Table of Contents

As filed with the Securities and Exchange Commission on December 20, 2024

Registration No. 333-   

 

 

 

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D.C. 20549

 

 

FORM S-1

REGISTRATION STATEMENT

UNDER

THE SECURITIES ACT OF 1933

 

 

Venture Global, Inc.

(Exact Name of Registrant as Specified in Its Charter)

 

 

 

Delaware   4924   93-3539083

(State or Other Jurisdiction of

Incorporation or Organization)

 

(Primary Standard Industrial

Classification Code Number)

  (I.R.S. Employer
Identification Number)

1001 19th Street North, Suite 1500

Arlington, VA, 22209

(202) 759-6740

(Address, Including Zip Code, and Telephone Number, Including Area Code, of Registrant’s Principal Executive Offices)

 

 

Michael Sabel

Chief Executive Officer, Executive Co-Chairman and Founder

Keith Larson

General Counsel and Secretary

Venture Global, Inc.

1001 19th Street North, Suite 1500

Arlington, VA, 22209

(202) 759-6740

(Name, Address, Including Zip Code, and Telephone Number, Including Area Code, of Agent For Service)

 

 

 

Copies to:

Richard D. Truesdell, Jr., Esq.
Marcel R. Fausten, Esq.

Joze Vranicar, Esq.

Davis Polk & Wardwell LLP
450 Lexington Avenue
New York, New York 10017
(212) 450-4000

 

Michael J. Hong, Esq.

David P. Armstrong, Esq.
Ryan J. Dzierniejko, Esq.
Skadden, Arps, Slate, Meagher & Flom LLP
One Manhattan West, 395 9th Ave,
New York, New York 10001
(212) 735-3000

 

 

Approximate date of commencement of proposed sale to the public: As soon as practicable after the effective date of this registration statement.

If any of the securities being registered on this form are to be offered on a delayed or continuous basis pursuant to Rule 415 under the Securities Act of 1933, check the following box. ☐

If this form is filed to register additional securities for an offering pursuant to Rule 462(b) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. ☐

If this form is a post-effective amendment filed pursuant to Rule 462(c) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. ☐

If this form is a post-effective amendment filed pursuant to Rule 462(d) under the Securities Act, check the following box and list the Securities Act registration statement number of the earlier effective registration statement for the same offering. ☐

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company or an emerging growth company. See the definitions of ‘‘large accelerated filer,’’ ‘‘accelerated filer,’’ ‘‘smaller reporting company’’ and ‘‘emerging growth company’’ in Rule 12b-2 of the Exchange Act.

 

Large accelerated filer  

  

Accelerated filer 

 

Non-accelerated filer      Smaller reporting company  
     Emerging growth company  

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 7(a)(2)(B) of the Securities Act. ☐

The registrant hereby amends this registration statement on such date or dates as may be necessary to delay its effective date until the registrant shall file a further amendment which specifically states that this registration statement shall thereafter become effective in accordance with Section 8(a) of the Securities Act of 1933 or until the registration statement shall become effective on such date as the Commission, acting pursuant to said Section 8(a), may determine.

 

 

 


Table of Contents

The information in this preliminary prospectus is not complete and may be changed. These securities may not be sold until the registration statement filed with the Securities and Exchange Commission is effective. This preliminary prospectus is not an offer to sell these securities nor a solicitation of an offer to buy these securities in any jurisdiction where the offer or sale is not permitted.

 

SUBJECT TO COMPLETION, DATED     , 2024

PRELIMINARY PROSPECTUS

     Shares

 

LOGO

Venture Global, Inc.

Class A Common Stock

 

 

Venture Global, Inc., or the Company, is offering   shares of its Class A common stock.

This is our initial public offering and no public market currently exists for our Class A common stock. We anticipate that the initial public offering price will be between $   and $   per share.

Upon completion of this offering, we will have two classes of common stock, Class A common stock and Class B common stock. Each share of Class A common stock is entitled to one vote per share. Each share of Class B common stock is entitled to ten votes per share. Holders of our Class A common stock and Class B common stock vote together as a single class on all matters, except as otherwise set forth in this prospectus or as required by applicable law. Each outstanding share of Class B common stock will convert automatically into one share of Class A common stock upon any transfer, except for certain exceptions and permitted transfers described in our amended and restated certificate of incorporation. The Class B common stock, which is held by Venture Global Partners II, LLC, or VG Partners, will represent approximately   % of the total combined voting power of our outstanding common stock following this offering (or approximately   % of the total combined voting power of our outstanding common stock if the underwriters exercise in full their option to purchase additional shares of our Class A common stock).

We have applied to list our Class A common stock on the New York Stock Exchange, or the NYSE, under the symbol “VG.”

After the completion of this offering, VG Partners will continue to beneficially own common stock representing more than 50% of the total combined voting power of our outstanding common stock eligible to vote in the election of directors. As a result, we will be a “controlled company” for the purposes of the NYSE listing requirements. See “Management—Status as a “Controlled Company” under the NYSE Listing Standards.”

 

 

Investing in our Class A common stock involves risks. See “Risk Factors” beginning on page 22.

 

 

Neither the Securities and Exchange Commission nor any state securities commission has approved or disapproved of these securities or determined if this prospectus is truthful or complete. Any representation to the contrary is a criminal offense.

 

     Per Share      Total  

Public offering price

   $           $       

Underwriting discounts and commissions(1)

   $        $    

Proceeds to us before expenses

   $        $    

 

(1)

See the section titled “Underwriting” for additional information regarding compensation payable to the underwriters.

The underwriters have the option for a period of 30 days to purchase up to an additional    shares of Class A common stock from us at the initial public offering price less underwriting discounts and commissions.

The underwriters expect to deliver the shares to purchasers on or about    , 2024.

 

 

Joint Bookrunning Managers

 

Goldman Sachs & Co. LLC*    J.P. Morgan*   BofA Securities
*(listed in alphabetical order)

 

ING   RBC Capital Markets  

Scotiabank

 

Mizuho

Santander  

SMBC Nikko

  MUFG   BBVA
Loop Capital Markets     Natixis     Deutsche Bank Securities

Prospectus dated     , 2024


Table of Contents

LOGO


Table of Contents

TABLE OF CONTENTS

 

 

 

     Page  

Market and Industry Data

     ii  

Trademarks and Service Marks

     ii  

Stock Split

     ii  

Basis of Presentation

     ii  

Certain Important Terms

     iii  

Prospectus Summary

     1  

Risk Factors

     22  

Special Note Regarding Forward-Looking Statements

     96  

Use of Proceeds

     100  

Dividend Policy

     101  

Capitalization

     102  

Dilution

     105  

Management’s Discussion and Analysis of Financial Condition and Results of Operations

     108  

LNG Industry Overview

     155  

Business

     175  

Management

     229  

Executive Compensation

     237  

Certain Relationships and Related Party Transactions

     254  

Principal Stockholders

     258  

Description of Capital Stock

     260  

Description of Material Financing

     267  

Material U.S. Federal Income and Estate Tax Consequences for Non-U.S. Holders of Common Stock

     282  

Shares Eligible For Future Sale

     285  

Underwriting

     288  

Legal Matters

     298  

Experts

     298  

Where You Can Find More Information

     299  

Index to Consolidated Financial Statements

     F-1  

 

 

We and the underwriters have not authorized anyone to provide any information or to make any representations other than those contained in this prospectus or in any free writing prospectuses we have prepared. We and the underwriters take no responsibility for, and can provide no assurance as to the reliability of, any other information that others may provide you. We and the underwriters are offering to sell, and seeking offers to buy, shares of Class A common stock only in jurisdictions where offers and sales are permitted. The information contained in this prospectus is accurate only as of the date of this prospectus, regardless of the time of delivery of this prospectus or of any sale of Class A common stock.

For Investors Outside of the United States: We and the underwriters have not done anything that would permit this offering, or possession or distribution of this prospectus, in any jurisdiction where action for that purpose is required, other than the United States. Persons outside of the United States who come into possession of this prospectus must inform themselves about, and observe any restrictions relating to, the offering of the shares of our Class A common stock and the distribution of this prospectus outside of the United States.

Through and including     , 2024 (25 days after the date of this prospectus), all dealers that buy, sell or trade our Class A common stock, whether or not participating in this offering, may be required to deliver a prospectus. This is in addition to the dealers’ obligation to deliver a prospectus when acting as underwriters and with respect to their unsold allotments or subscriptions.

 

i


Table of Contents

MARKET AND INDUSTRY DATA

This prospectus includes industry and market data, including our general expectations and market position, market opportunity and market size, as well as future growth rates relating to our market opportunity and the industry and markets in which we operate, that is based on industry publications and other published industry sources prepared by third parties, including IGU World LNG Report, S&P Global Commodity Insights and U.S. Energy Information Administration, EIA, International Energy Outlook, as well as filings of public companies in our industry and other publicly available information (including from government and industry sources). In some cases, we do not expressly refer to the sources from which this data is derived. Industry publications and surveys generally state that the information contained therein has been obtained from sources believed to be reliable. Although we believe the industry and market data to be reliable as of the date of this prospectus, this information could prove to be inaccurate. Industry and market data could be wrong because of the method by which sources obtained their data and because information cannot always be verified with complete certainty due to the limits on the availability and reliability of raw data, the voluntary nature of the data gathering process and other limitations and uncertainties.

Moreover, projections, assumptions and estimates of our future performance and the future performance of the industry in which we operate, including future growth rates and related estimates, forecasts and projections relating to the industry in which we operate and our market position, market opportunity and market size, are prospective in nature. Any such projections, assumptions and estimates are necessarily subject to a high degree of uncertainty and risk due to a variety of factors, including those described in the sections captioned “Risk Factors” and “Special Note Regarding Forward-Looking Statements” elsewhere in this prospectus. These and other factors could cause results, and any such projections, assumptions and estimates, to differ materially from those expressed in the projections, assumptions and estimates made by third parties and by us. You are cautioned not to give undue weight to such projections, assumptions and estimates.

TRADEMARKS AND SERVICE MARKS

The Venture Global logos, and other trade names, trademarks, or service marks of Venture Global appearing in this prospectus are the property of Venture Global. Other trade names, trademarks, or service marks appearing in this prospectus are the property of their respective holders. Solely for convenience, trade names, trademarks, and service marks referred to in this prospectus appear without the ®, , and SM symbols, but those references are not intended to indicate, in any way, that we will not assert, to the fullest extent under applicable law, our rights or that the applicable owner will not assert its rights, to these trade names, trademarks, and service marks.

STOCK SPLIT

After the effectiveness of the registration statement of which this prospectus forms a part and before the automatic conversion of all shares of Class A common stock held by VG Partners immediately prior to the completion of this offering into an equal number of shares of Class B common stock, which will occur immediately prior to the completion of this offering, we will effectuate a  -for-1 forward stock split, or the Stock Split, of our Class A common stock. The audited consolidated financial statements and unaudited condensed consolidated financial statements and related notes to those statements, included elsewhere in this prospectus, have not been adjusted for the Stock Split. Unless otherwise indicated, all other share and per share data in this prospectus have been retroactively adjusted, where applicable, to reflect the Stock Split as if it had occurred at the beginning of the earliest period presented.

BASIS OF PRESENTATION

We have made rounding adjustments to some of the figures included in this prospectus. Accordingly, numerical figures shown as totals in some tables may not be an arithmetic aggregation of the figures that precede them. Unless otherwise indicated, all references to “U.S. dollars,” “dollars” and “$” in this prospectus are to the lawful currency of the United States of America.

 

ii


Table of Contents

CERTAIN IMPORTANT TERMS

Unless otherwise indicated or the context otherwise requires, as used in this prospectus:

 

   

Bcf means billion cubic feet;

 

   

Bcf/d means billion cubic feet per day;

 

   

Bcf/yr means billion cubic feet per year;

 

   

bolt-on expansion liquefaction capacity means the incremental capacity that can be generated by our projects as a consequence of potential expansions to our existing or planned projects;

 

   

COD means the commercial operations date, which is the first day of commercial operations at a project or a phase of a project, as applicable, as specifically defined in the relevant post-COD SPAs, and which does not occur unless and until: (i) all of the facilities comprising the relevant project, or phase thereof, have been completed and commissioned, including any ramp up period, (ii) the project or phase thereof is capable of delivering LNG in sufficient quantities and necessary quality to perform all of its obligations under such post-COD SPAs, and (iii) the applicable project company has notified the customer under the post-COD SPAs;

 

   

commercial operations means the production period commencing after the occurrence of COD at a project or a phase of a project, as applicable;

 

   

commissioning or commissioning phase means, with respect to our LNG projects, the phase of development where our facilities undergo certain required performance and reliability testing, which includes (i) the sequential start-up and testing of certain key equipment (e.g., liquefaction trains) as it is installed during construction and (ii) the testing and tuning of the full integrated LNG project after all key equipment and modules have passed their individual performance tests;

 

   

commissioning cargos means the LNG cargos produced by us during the commissioning phase of an LNG project, which commences once a project produces its first quantities of LNG and ends once a project, or phase thereof, achieves COD. Proceeds from the sale of commissioning cargos are recognized in our financial statements as a reduction to the cost basis of construction in progress until assets are placed in service from an accounting perspective, the timing of which may differ from COD. After assets are placed in service from an accounting perspective, the proceeds are recognized through revenue;

 

   

the Company means Venture Global, Inc., but not its subsidiaries;

 

   

CP Express means Venture Global CP Express, LLC;

 

   

CP2 means Venture Global CP2 LNG, LLC;

 

   

CP3 means Venture Global CP3 LNG, LLC;

 

   

Delta means Venture Global Delta LNG, LLC;

 

   

Delta Express means Venture Global Delta Express, LLC;

 

   

DOE means the United States Department of Energy;

 

   

DPU means delivered at place unloaded, which, with respect to LNG SPAs, requires the seller to deliver and unload LNG at one or more designated destinations;

 

   

EPC means engineering, procurement and construction;

 

   

EPCM means engineering, procurement, and construction management, which entails certain supervision, management, and co-ordination of EPC and other construction interface work;

 

   

excess capacity or excess LNG means the amount of LNG that is produced by our liquefaction facilities that is in excess of the nameplate capacity;

 

iii


Table of Contents
   

FERC means the Federal Energy Regulatory Commission;

 

   

FID means the final investment decision with respect to the development of a project or a phase thereof, which, with respect to an LNG project, requires that the project has secured (i) all of the debt and equity financing arrangements necessary to fully construct, commission, and operate such project or phase thereof and (ii) all of the necessary permits to construct, operate, and export LNG;

 

   

FOB means free on board which, with respect to LNG SPAs, requires the seller to deliver and load LNG onto the buyer’s LNG tankers at the seller’s export terminal;

 

   

FTA means a free trade agreement;

 

   

Gator Express means Venture Global Gator Express, LLC;

 

   

Henry Hub means the final settlement price (in $ per MMBtu) for the New York Mercantile Exchange’s Henry Hub natural gas futures contract for the month in which a relevant cargo’s delivery window is scheduled to begin;

 

   

Legacy VG Partners means Venture Global Partners, LLC;

 

   

liquefaction train or train means a liquefaction production unit that cools natural gas to a liquid state;

 

   

LNG means liquefied natural gas, or methane, supercooled to -260°F and converted into a liquid state, which reduces it to 1/600th of its original volume, enabling large quantities of natural gas to be loaded and shipped by LNG tankers;

 

   

Mcf/d means million cubic feet per day;

 

   

MMBtu means million British thermal units;

 

   

MMt means million tonnes;

 

   

mtpa means million tonnes per annum, which is a common unit of measurement for annual LNG production;

 

   

nameplate capacity means, unless the context otherwise requires, the conservative measure of LNG production capability, based on vendor guaranteed LNG output of each of our facilities;

 

   

natural gas means any hydrocarbons that are gaseous at standard temperature and pressure;

 

   

NTP means a formal notice to proceed issued under our EPC contracts, procurement contracts or other construction contracts, as applicable;

 

   

NYSE means the New York Stock Exchange;

 

   

peak production capacity means the total combined amount of LNG that our liquefaction facilities are anticipated to produce, which is the sum of such facility’s expected nameplate capacity and excess capacity (or excess LNG);

 

   

post-COD SPA means an SPA for the sale and purchase of LNG after COD has occurred for a particular project or phase thereof;

 

   

Pre-IPO Stockholders means VG Partners and each other holder of shares of our common stock outstanding immediately prior to consummation of this offering;

 

   

regasification means the process of heating LNG to convert it from a liquid to gaseous state after the LNG is offloaded from an LNG carrier;

 

   

SPA or LNG SPA means LNG sales and purchase agreement;

 

   

stick-built means a traditional labor-intensive construction method where raw materials, parts and components are delivered to site for on-site fabrication, assembly and construction by very large workforces;

 

iv


Table of Contents
   

Stock Split means the  -to-one forward stock split of our Class A common stock, which we will effectuate after the effectiveness of the registration statement of which this prospectus forms a part and before the completion of this offering, as described under “Stock Split.”

 

   

Tcf means trillion cubic feet;

 

   

TCP means TransCameron Pipeline, LLC;

 

   

total contracted revenue means, as of a particular date, the sum, for the remainder of the term for all of our post-COD SPAs then in effect, of (i) the volume weighted average of the fixed facility charge component for all such post-COD SPAs for each project or project phase, multiplied by the contracted volumes for all such post-COD SPAs for the applicable project or project phase, in each case adjusted for inflation (assuming that 17.5% of the fixed facility charge component increases by 2.5% annual inflation every year following the first full year after COD), and (ii) the lifting revenue that would be earned for all such post-COD SPAs, assuming, for illustrative purposes only, all volumes contracted under each such post-COD SPA are lifted at an assumed Henry Hub gas price per MMBtu of $4.00 per MMBtu, in each case using a conversion factor of MMBtu to mtpa of 52. See “Risk Factors—Risks Relating to Our Business—Total contracted revenue is based on certain assumptions and is presented for illustrative purposes only and actual sales under our SPAs may differ materially from such illustrative operating results”;

 

   

Trigger Date means the first time at which either (i) VG Partners and its permitted transferees, collectively, no longer beneficially own more than 50% of the combined voting power of our outstanding common stock entitled to vote generally in the election of directors, or (ii) we fail to qualify as a “controlled company” (or similar) under the applicable stock exchange rules;

 

   

Venture Global, we, our, us or similar terms mean Venture Global, Inc. and its subsidiaries, collectively;

 

   

VG Commodities means Venture Global Commodities, LLC;

 

   

VG Partners means Venture Global Partners II, LLC, our controlling shareholder;

 

   

VGCP means Venture Global Calcasieu Pass, LLC;

 

   

VGLNG or Venture Global LNG means Venture Global LNG, Inc.; and

 

   

VGPL means Venture Global Plaquemines LNG, LLC.

 

 

v


Table of Contents

PROSPECTUS SUMMARY

This summary highlights information contained elsewhere in this prospectus. This summary may not contain all of the information that you should consider before deciding to invest in our Class A common stock. You should read this entire prospectus carefully, including the “Risk Factors” section and the consolidated financial statements and the notes to those statements and management’s discussion and analysis thereof included elsewhere in this prospectus, before making an investment decision to purchase our Class A common stock.

Overview

Our Company

Venture Global has fundamentally reshaped the development and construction of liquefied natural gas production, establishing us as a rapidly growing company delivering critical LNG to the world. Our innovative and disruptive approach, which is both scalable and repeatable, allows us to bring LNG to a global market years faster and at a lower cost. We believe supplying this clean, affordable fuel promotes global energy security and is essential to meeting growing global demand.

Natural gas is one of the most important resources worldwide and is required to generate reliable electricity that underpins economic development and drives industry. Once natural gas is supercooled to -260°F, it converts to liquid form and reduces to 1/600th of its original volume, enabling large quantities of natural gas to be loaded and shipped by LNG tankers. The resulting LNG can be transported to international markets that lack domestic supply, displacing more carbon intensive sources of energy such as coal, diesel, and heavy fuel oil, and serving as an integral part of a cleaner energy future. We believe our business model has demonstrated that in a competitive commodity market, lower cost and overall faster delivery wins market share. Our approach capitalizes on both of these advantages, supporting significant additional growth opportunities.

Our Projects

We are commissioning, constructing, and developing five natural gas liquefaction and export projects near the Gulf of Mexico in Louisiana, utilizing our unique “design one, build many” approach. Each project is designed or is being developed to include an LNG facility and associated pipeline systems that interconnect with several interstate and intrastate pipelines to enable the delivery of natural gas into the LNG facility. As illustrated by the chart below, our five current projects are being designed to deliver a total expected peak production capacity of 143.8 mtpa, which consists of an aggregate of 104.4 mtpa expected nameplate capacity and an aggregate of 39.4 mtpa of expected excess capacity. These amounts do not account for any potential bolt-on expansion liquefaction capacity. The expected nameplate capacity of our facilities measures the minimum operating performance thresholds guaranteed by the equipment providers, and the expected excess capacity represents the additional LNG that we aim to produce above such guaranteed amounts. Although COD has not yet occurred under the post-COD SPAs for any of our projects, we have been generating proceeds from the sale of commissioning cargos at the Calcasieu Project since the first quarter of 2022, and expect to do so at each of our other projects during commissioning prior to achieving COD for the relevant project or phase of a project.

 

1


Table of Contents

LOGO

 

(1)

Targets based on, among other things, anticipated timeframes for the receipt of certain regulatory approvals as described in “Business—Governmental Regulation.”

(2)

Anticipated based on capacity, scale, location and infrastructure. Subject to regulatory review and approval, among other things, and may change based on design considerations, engagement with contractors, and other factors.

Our Project Development and Construction Approach

The traditional approach to developing large-scale LNG facilities involves very large, highly customized, stick-built projects consisting of two to three liquefaction trains that are constructed almost entirely onsite by vast workforces. In addition, many of these large stick-built projects are built in remote locations far from concentrated sources of experienced construction workforces, adding to their execution risks. Using this traditional approach, construction can last well over five years and in some cases has lasted nearly a decade.

In contrast, our project development and construction approach utilizes proven liquefaction system technology and equipment in a unique mid-scale, factory-fabricated configuration that we developed. Instead of two or three large, complex liquefaction trains, the Calcasieu Project and the Plaquemines Project utilize 18 and 36 mid-scale factory-fabricated liquefaction trains, respectively. We expect to use the same approach and technology at the CP2 Project, the CP3 Project and the Delta Project. Our modules are built and assembled off-site at manufacturing and fabrication facilities in Italy and then shipped to our project sites fully-assembled and packaged for installation, allowing onsite work to progress in parallel. We believe our innovative configuration, long-term equipment contracting strategy and hands-on project management approach significantly reduces construction and installation costs, as well as construction time and schedule risk, thereby allowing us to be more cost-competitive in the LNG market while also producing substantial amounts of commissioning cargos and related cash proceeds. For example, our initial two projects, the Calcasieu Project and the Plaquemines Project, in each case, began producing LNG approximately two and a half years after its final investment decision, while significant construction work remained ongoing. The chart below illustrates the length of time the Calcasieu Project and the Plaquemines Project took to achieve first production of LNG after achieving FID relative to other projects that also achieved FID substantially contemporaneously and are not producing LNG as of the date of this prospectus.

LOGO

 

2


Table of Contents

While traditional LNG projects often rely on bespoke designs and configurations, our approach, leveraging factory-fabricated equipment manufactured with our “design one, build many” method, allows us to apply the lessons we learn at each project to our subsequent projects, with the goal of continuously improving our execution, accelerating construction timelines, reducing costs, and expanding production. We believe we will continue to benefit from this virtuous cycle as we grow.

Gas Supply and Transportation

We have entered into a portfolio of natural gas supply agreements with domestic natural gas suppliers to furnish feed gas to the Calcasieu Project and the Plaquemines Project for liquefaction and power generation. We have also entered into multiple transport capacity agreements with interstate pipeline companies to provide natural gas transportation to the Calcasieu Project and the Plaquemines Project via short-run lateral pipelines. The CP2 Project has already entered into agreements with third parties for substantial firm transportation capacity and is developing its own pipeline. The CP3 Project and the Delta Project will require their own proposed pipeline routes and we aim to enter into transportation agreements with interstate pipeline companies in connection with the CP2 Project, the CP3 Project and the Delta Project as development progresses.

LNG Sales – Commissioning

By design, conventional, stick-built projects generally only engage in several months of commissioning production, thereby limiting the number of cargos produced before full commercial operations occur. Due to our unique modular development approach and configuration consisting of many mid-scale liquefaction trains, which are delivered and installed sequentially, it is necessary to commission and test our LNG facilities sequentially over a longer period of time than traditional LNG facilities with substantially fewer, larger-scale liquefaction trains. The commissioning of the liquefaction trains at our facilities begins while portions of our facilities remain under construction.

This important reliability and technical requirement results in earlier production of LNG than with traditional LNG facilities. We believe this earlier production of LNG positions us to produce a substantial number of commissioning cargos for each of our LNG projects, generating proceeds that may be used to support any remaining construction work or fund subsequent projects and future growth. As an example of this, on March 1, 2022, we announced the successful loading and departure of our first cargo of LNG from the Calcasieu Project, just over two and a half years from our final investment decision for the project. By September 30, 2024, we had loaded and sold 342 LNG commissioning cargos and received approximately $19.6 billion in gross proceeds from such commissioning cargos.

LNG Sales – Post-COD SPAs

The project companies for the Calcasieu Project, the Plaquemines Project and the CP2 Project have signed LNG sales and purchase agreements, or SPAs, to sell LNG based on a pre-determined pricing formula that commences after we achieve the commercial operations date, or COD, of the relevant project or phase thereof. Under each such post-COD SPA, COD does not occur unless the applicable project company has notified such customer that (i) all of the project’s facilities have been completed and commissioned, including any ramp up period, and (ii) the project is capable of delivering LNG in sufficient quantities and necessary quality to perform all of its obligations under such post-COD SPA.

As of September 30, 2024, we have executed 39.25 mtpa of such post-COD SPAs with a well recognized set of third party customers that we believe constitute one of the strongest portfolios of institutional LNG buyer credits in the world. Approximately 95% of our contracted post-COD SPAs – or 37.45 mtpa of such 39.25 mtpa – are 20-year fixed price agreements, providing a long-term stream of contracted cash flow. We have also

 

3


Table of Contents

executed 1.8 mtpa of post-COD SPAs on a short- and medium-term basis and we plan to continue to optimize our portfolio balancing profit, duration, and risk.

Excess Capacity

LNG projects are typically able to achieve production beyond their guaranteed nameplate capacities. For many traditional large international stick-built projects, generating additional production capacity generally requires substantial incremental equipment and construction, with associated injections of capital. By comparison, we believe our projects will have the potential to produce materially beyond their nameplate capacities, with modest incremental capital investment because of our modular design as well as redundancy features inherent in our project design.

We aim to construct and maintain LNG facilities that are capable, in most cases, of producing excess capacity of at least 30% of their guaranteed nameplate capacity, which provides the potential for additional cash proceeds from our projects. Any such excess capacity will generally be available to us to sell on a short-, medium-, or long-term basis, providing flexibility to optimize pricing. With respect to the Calcasieu Project, our inaugural project, we expect to produce excess capacity of slightly less than 30% of its nameplate capacity and we have received FERC approval for a maximum production capacity of 12.4 mtpa. We have contracted to sell a portion of the Calcasieu Project excess capacity to a third-party pursuant to a long-term SPA.

Optimization and Bolt-on Expansion Opportunities

Our projects also offer potential optimization, increased capacity and expansion opportunities. In particular, our projects are sited and designed with the intention of allowing for bolt-on expansions, incorporating laydown area, redundancies across the facility infrastructure and our mid-scale factory-fabricated liquefaction trains. Subject to receiving the requisite regulatory approvals, we intend to pursue the development of these expansion opportunities beyond our current combined expected peak production capacity of 143.8 mtpa. Any incremental equipment would benefit from pre-existing plant facilities and related infrastructure (such as marine offloading facilities, LNG storage tanks and perimeter walls). We aim to place up to an aggregate of approximately 35.3 mtpa of additional bolt-on expansion liquefaction capacity of incremental modular mid-scale liquefaction trains at most of our current projects.

Potential Additional LNG Projects and Further Integration

In addition to our current projects, we regularly explore opportunities, both domestic and international, to develop or acquire other potential natural gas liquefaction and export projects, as well as other complementary, synergistic or ancillary projects, in the ordinary course of our business. As described below, we have already engaged in substantial activities to establish complementary pipeline projects, LNG tanker and regasification business lines that could be leveraged for other potential natural gas liquefaction and export projects in the future. Our experienced project execution team, who have deep industry expertise in the LNG, shipping, midstream and construction industries, possess the institutional agility and capital to rapidly evaluate and act upon opportunities as they arise and we believe differentiate us from our competitors.

Pipeline Projects

We are in the advanced stages of development to establish complementary gas transportation for our development projects. As an example, we have partnered with WhiteWater Midstream, LLC, a Texas-based pipeline developer and operator, and entered into a limited liability company agreement with one of their affiliates pursuant to which we hold 50% of the equity interests in Blackfin Pipeline Holdings, LLC, through which we will jointly develop, permit, site and indirectly own the approximately 190 mile Blackfin pipeline

 

4


Table of Contents

project, a long-haul 48-inch intrastate pipeline designed to facilitate the transportation of Permian sourced gas from the Matterhorn Express pipeline to certain interconnecting pipelines, including the CP Express Pipeline. Under the limited liability company agreement, we have agreed to fund certain construction and development costs and seek to arrange a financing to support the Blackfin pipeline project. We believe that gas transportation projects such as this will help further integrate major sources of gas supply with the projects we may develop in the future.

Shipping

In order to vertically integrate our business and expand our customer base to premium markets that have no or limited LNG transportation resources, we have contracted to acquire nine LNG tankers being constructed by two of the premier shipbuilders in South Korea, with two already delivered. The remaining LNG tankers are under construction and are scheduled to be delivered on a rolling basis through 2026. All nine of such newbuild LNG tankers will be primarily fueled by LNG and are designed with best-in-class environmental and efficiency technology. LNG tankers which run on LNG, such as ours, can reduce CO2 emissions by 20-30% compared to tankers that operate with heavy fuel oil. We plan to have our tankers equipped with engines that are designed to significantly reduce methane slip by approximately 66% or more, versus the standard engines used on legacy LNG carriers. Also, we believe our LNG tankers are far more energy efficient than what is typical, due to a hydrodynamic hull design, which is expected to reduce propulsion power by approximately 10%, and the implementation of an air lubrication system that is intended to reduce hull friction and propulsion power requirements by approximately 3%. We have also executed two short-term charters for additional LNG tankers, which were delivered in August and September 2024, bringing our total shipping portfolio to a total of eleven tankers. We believe these LNG tankers will support our ability to optimize LNG marketing and sales and differentiate us from many other LNG exporters in North America.

Regasification

We are also pursuing opportunities to secure LNG regasification capacity in key import markets. As part of this initiative, we have acquired firm regasification facility capacity at the largest LNG regasification terminal in Europe, Grain LNG, in the United Kingdom, which we expect will allow us to import 42 LNG cargos per year from approximately 2029 until 2045 (apart from a limited period). Additionally, we have secured approximately 1 mtpa of LNG regasification capacity at the new Alexandroupolis LNG receiving terminal in Greece for five years, beginning in 2025. Our capacity will account for approximately 25% of the total terminal capacity at Alexandroupolis, or approximately 12 cargos annually. We believe these contracted capacities will allow us to supply LNG and regasified natural gas directly into the European market to current and additional downstream customers. As in the case of our shipping business, many LNG developers have elected to forego integrating regasification into their broader business. Relatedly, many LNG customers lack direct access to regasification capacity. We believe our regasification access will allow us to offer spot and term customers a differentiated service, ultimately positioning us to win market share.

Our Strengths

Our business has a number of competitive strengths, including the following:

 

   

Industry leading growth in the critical global LNG market. We believe that we are the fastest growing developer of LNG facilities in the competitive global supply market. Since the second half of 2019, Venture Global and its affiliates have reached final investment decision for three large-scale, greenfield liquefaction facilities (consisting of the Calcasieu Project and Phase 1 and Phase 2 of the Plaquemines Project) being developed in the United States. We believe that, during this same period, no other developer achieved such a milestone for more than a single large-scale infrastructure project in the

 

5


Table of Contents
 

world. We expect to increase our LNG production capacity further as we continue our work to optimize our existing projects and develop the CP2 Project, the CP3 Project, the Delta Project, bolt-on and other expansion opportunities, and other investments.

 

   

Accelerated construction schedule and low-cost LNG model. We believe that our disruptive and innovative configuration and owner-led engineering, procurement and construction approach reduces our construction and installation costs, construction time and construction schedule risk, thereby reducing overall project costs and enabling us to produce and sell LNG on an accelerated basis to our customers, as a result of the following:

 

   

Focus on minimizing the time to first LNG. At our first project, the Calcasieu Project, we were able to produce and load LNG for sale approximately two and a half years after the final investment decision, while simultaneously commissioning and constructing the facility, which is substantially faster than the industry average of five years. Although our second project is designed to produce twice the amount of LNG as our first project, we achieved first production of LNG and commenced loading LNG for sale on a similar timeframe. We also aim to improve the pace of bringing incremental trains online at each of our projects.

 

   

Construction and installation execution. Manufacturing our mid-scale, factory-fabricated liquefaction trains, power equipment, gas pre-treatment modules and pipe racks off-site at fabrication facilities allows site works to progress in parallel. Our liquefaction trains and pre-treatment modules are tested and delivered ready to install, reducing on-site labor and potential weather risk while shortening construction timelines and improving overall project safety. Fabrication and installation efficiencies are achieved as the various trains, equipment, and modules are installed on-site and commence production incrementally. Using our “design one, build many” approach, lessons learned from construction, installation, and commissioning work at the Calcasieu Project are being carried over to the Plaquemines Project and our subsequent projects. Further, using our owner-led development model, we actively manage the construction activity and the schedule for certain scopes of work undertaken by our key contractors. In addition, we have built an internal EPCM capability, securing a team of experienced leaders and professionals from the EPC industry, primarily with prior relevant experience constructing the Calcasieu Project and the Plaquemines Project facilities.

 

   

Incremental commissioning and LNG production proceeds provide substantial cash proceeds. As each project’s liquefaction trains are brought online, sequentially, and early in construction, the project incrementally produces greater quantities of LNG that may be sold into the market. Once all individual components have been commissioned, production continues while we complete full commissioning of the integrated facility and conduct any carryover or rectification work. During such process, we complete performance testing of the entire fully-integrated facility and validate reliable operational performance. We expect that each project’s construction plan and sequencing will be designed to allow LNG to be produced, stored and loaded onto ships for export, and sold as commissioning cargos, generating cash proceeds.

 

   

Substantial ownership and direct oversight of a diversified LNG project portfolio. Venture Global seeks to own all or substantially all of the equity ownership in its current five LNG projects and any future projects. As of the date of this prospectus, we own 100% of the common equity interests in the Calcasieu Project, the Plaquemines Project, the CP2 Project, the CP3 Project and the Delta Project. Upon COD for the Calcasieu Project, we expect our ownership of the common equity interests in the Calcasieu Project to be reduced to approximately 77% (assuming that we service all future distributions on the Holdings Preferred Units until the commencement of COD in cash), after adjusting for the automatic conversion of the convertible preferred units in Calcasieu Holdings held by an outside equity investor. We believe that our significant ownership stake in our projects provides us with full managerial control, facilitating nimble decision-making and speed of execution.

 

6


Table of Contents
   

Stable, long-term cash flows and valuable commissioning cargos and excess cargos.

 

   

Long-term take-or-pay contracts with highly creditworthy offtakers. We anticipate that our business model will provide us with stable cash flows as a result of our long-term take-or-pay contracts to sell LNG. As of September 30, 2024, we have executed 39.25 mtpa of post-COD SPAs with a set of third party customers that we believe constitute one of the strongest portfolios of institutional LNG buyer credits in the world. The entire expected nameplate capacity for the Calcasieu Project (10 mtpa) and the Plaquemines Project (20 mtpa), and 9.25 mtpa of the CP2 Project, have been contracted under such SPAs. Our third-party post-COD SPAs as of September 30, 2024 represent expected total contracted revenue of approximately $107 billion over the life of such SPAs. Our total contracted revenue is illustrative only and is based on a number of important assumptions. See “Risk Factors—Risks Relating to Our Business—Total contracted revenue is based on certain assumptions and is presented for illustrative purposes only and actual sales under our SPAs may differ materially from such illustrative operating results.” The weighted average life of all of our post-COD SPAs is approximately 19 years, providing a long-term runway of reliable cash flows.

 

   

Valuable and substantial commissioning cargo and excess cargo cash proceeds. Prior to achieving COD under our post-COD SPAs, our post-COD SPAs permit us to generate and sell commissioning cargos to customers at market-based prices, which we believe can unlock significant value to Venture Global. This approach has the potential dual benefit of helping to mitigate risks related to commencement of commercial operations and generating significant cash flow that can be reinvested into the business. For example, since the commencement of commissioning work, the Calcasieu Project has loaded and sold 342 commissioning cargos as of September 30, 2024 and received approximately $19.6 billion in gross proceeds from such commissioning cargos. In addition, after COD occurs under our post-COD SPAs, to the extent not already contracted with third parties, we can sell any LNG generated by our projects above the nameplate capacity to customers at market-based prices, providing potential revenue upside over the long term. Proceeds generated from the sale of commissioning cargos and excess cargos provide us with additional cash proceeds and contingency to support project completion and can help fund the development of our other projects.

 

   

Strategic project locations with capacity for substantial expansions. We are developing our current portfolio of projects on strategic locations in Louisiana, which we believe have significant advantages relative to other locations in the United States. Our current projects are located near or within a reasonable distance from several major interstate and intrastate natural gas pipelines with available capacity that we believe will be sufficient to supply the feed gas required for our projects. We believe these project sites are well-placed and allow us to access liquid and robust natural gas trading areas and obtain competitively priced natural gas for our customers. Our current project portfolio offers geographic diversification within Louisiana. The Calcasieu Project, the CP2 Project and the CP3 Project are located at or near the mouth of the Calcasieu Ship Channel, and the Plaquemines Project and the Delta Project are located approximately 300 miles east and are sited next to the Mississippi River, each of which provides ready access to our facilities from the Gulf of Mexico. Since they are located at or near the mouth of the Calcasieu Ship Channel, the Calcasieu Project, the CP2 Project and the CP3 Project sites’ geography also allow for faster entry into and exit from our berthing docks relative to many other facilities in the region. Our current projects are also located in close proximity to major population centers, providing ease of access for workers and transportation of materials. The Calcasieu Project and Plaquemines Project sites also benefit from full road and water access, and buffer lands to facilitate deliveries and serve as laydown areas, and we expect sites of the CP2 Project, the CP3 Project and the Delta Project to benefit from the same access and buffer lands. We believe our current project sites provide significant opportunities for bolt-on expansions that would benefit from

 

7


Table of Contents
 

pre-existing plant facilities and related infrastructure (such as common pipe racks, marine offloading facilities and perimeter walls). Moreover, we believe Louisiana is a favorable legal, regulatory and political jurisdiction for our projects.

 

   

LNG shipping and regasification capabilities to supply new customers and to support existing customers. We are assembling a fleet of at least 11 LNG tankers to provide additional optionality to spot and term customers and to service contracts with transportation or delivery components. We have also acquired firm regasification facility capacity at the Grain LNG terminal, Europe’s largest LNG regasification terminal, in the United Kingdom to import 42 LNG cargos per year from approximately 2029 until 2045 (apart for a limited period). Additionally, we have secured approximately 1 mtpa of LNG regasification capacity at the new Alexandroupolis LNG receiving terminal in Greece for five years, beginning in 2025, which equates to approximately 12 cargos annually. We believe that such shipping and regasification capabilities will support our ability to optimize LNG marketing, sales, and logistics to reach new markets and customers.

 

   

Experienced management team aligned with stakeholders.

 

   

Industry-leading team. Our management team possesses deep experience across all parts of the LNG industry with a proven development and operational track record. We believe that the collective quality and experience of our team, coupled with our relationships with our contractors, customers and consultants, enable us to move quickly to continue to take advantage of the North American LNG market opportunity. Further, as of September 30, 2024, we have assembled a broader team of over 1,400 employees globally.

 

   

Exemplary safety record. Notwithstanding the rapid construction progress that we have achieved, the Calcasieu Project and Plaquemines Project have maintained exemplary safety records. Our projects have substantially outperformed the national average of a 1.9 Total Recordable Incident Rate, or TRIR, for 2023, which represents US Bureau of Labor Statistics Heavy Construction Industry recordable incidents per one hundred workers per year. On average, our safety record exceeds the industry average by over ten times with an aggregate TRIR of 0.17 for approximately 84.5 million hours of work on an aggregate basis as of September 30, 2024. As of September 30, 2024, the Calcasieu Project executed approximately 25.1 million work hours with a TRIR of 0.10 and the Plaquemines Project executed approximately 59.4 million work hours with a TRIR of 0.19.

 

   

Committed to environmental and community initiatives. Our management team is committed to an environmentally sound and community-friendly approach to the development and operation of our projects in conjunction with our key stakeholders. We aim to establish close relationships with the communities where our projects are located by fueling local economic growth, job creation, and skills training, while also engaging in wetlands restoration work. In addition, we have decided to use environmentally-sensitive design features (e.g., electrically-driven motors, air cooling throughout the projects, combined cycle power, and state of the art, full containment storage tanks which seek to eliminate methane release from stored LNG), and are pursuing an initiative to develop certain CCS facilities for our projects.

Our competitive strengths are subject to several risks and competitive challenges. Please read “Risk Factors” and “Business—Competition.”

Our Business and Growth Strategies

Since our founding in 2013, we have grown rapidly from a two-person company into the formidable energy market disruptor we are today. As of September 30, 2024, we employ over 1,400 people globally and are commissioning, constructing, and developing five natural gas liquefaction and export projects. We also now own

 

8


Table of Contents

or lease or have an option to own or lease nearly 6,000 acres of strategically located land in Louisiana, much of which benefits from significant deep-water frontage. Although we have a limited operating history and did not generate any proceeds prior to 2022, as of September 30, 2024, we have raised approximately $54 billion of capital and generated approximately $19.6 billion in gross proceeds from sales of commissioning cargos, resulting in approximately $14.2 billion of net proceeds. We have also executed 39.25 mtpa of post-COD SPAs as of September 30, 2024, and expect total contracted revenue of approximately $107 billion over the life of such SPAs. Notwithstanding these accomplishments, we are acutely focused on further growth and plan on pursuing the following three core drivers to expand our scale, profitability and impact on the global energy industry.

 

   

Develop, Construct and Operate New LNG Facilities – In addition to the Calcasieu Project and Plaquemines Project, which are undergoing construction and commissioning activities, we are currently developing, permitting, and advancing three projects: the CP2 Project, the CP3 Project and the Delta Project. Based on our success developing, permitting, financing and constructing the Calcasieu Project and the Plaquemines Project, we are confident in our ability to execute these additional projects and expect each facility to increase the cash proceeds we generate from LNG sales over time in a compounding fashion due to the following factors:

 

   

Rapid Return of Capital Enables Parallel Project Development – Unlike most industrial project developers who must wait years to recoup invested capital, our innovative approach to development allows us to generate cash proceeds from commissioning cargos at our projects which can potentially surpass the total costs of the projects prior to COD. Further, this accelerated return profile can also allow us to shift capital from one project under construction to a subsequent project, enabling us to develop multiple projects in parallel. In the case of the CP2 Project, we plan on utilizing cash proceeds from the Calcasieu Project and the Plaquemines Project to fund a substantial portion of construction.

 

   

Optimized LNG Sales – By recycling cash proceeds from one project to fund our subsequent projects, we aim to reduce our need for a critical mass of long-term SPAs for future projects (including the CP2 Project, CP3 Project and Delta Project), which are predominantly lower priced than short- and medium- term SPAs and typically required to support traditional project financing. Any production capacity from our projects that is not otherwise committed can be sold on a short-, medium- or long-term basis, including on a spot basis, providing flexibility to optimize the pricing for such capacity and allowing us to balance profit, duration and risk. As a result, while the Plaquemines Project and the CP2 Project are both designed as 20 mtpa nameplate capacity facilities, we expect the cash proceeds generated by the optimized cash proceeds at the CP2 Project to exceed the substantial LNG sales at the Plaquemines Project. We believe this virtuous cycle will compound with subsequent projects.

 

9


Table of Contents
   

Bolt-On Expansions

 

   

A distinctive benefit of our unique design is the ability to flexibly and economically expand liquefaction capacity by adding additional factory-made liquefaction trains and installing them at our existing projects. Bolt-on expansions were contemplated in the initial design and siting of our facilities. Such expansions benefit from substantial redundancy to support additional production capacity.

 

   

We intend to pursue these opportunities in the future and believe that we have the ability to add up to a total of approximately 35.3 mtpa of bolt-on expansion capacity across the Calcasieu Project, the Plaquemines Project, the CP2 Project, and the Delta Project as outlined below. No such expansions are currently contemplated at the CP3 Project due to its considerable 42.0 mtpa expected peak production capacity.

 

   

We aim to self-fund these expansions, reducing our reliance on lower-priced, longer-term contracts that are typically required to support traditional project financing. This strategy enables us to sell the production capacity from any such expansions on a short-, medium- or long-term basis, including on a spot basis, thereby providing flexibility to continually optimize the pricing for such capacity based on market conditions.

 

 

LOGO

 

(1)

Targets based on, among other things, anticipated timeframes for the receipt of certain regulatory approvals as described in “Business—Governmental Regulation.”

(2)

Anticipated based on capacity, scale, location and infrastructure. Subject to regulatory approval, among other things, and may change based on design considerations, regulatory review process, engagement with contractors, and other factors.

(3)

Potential bolt-on expansion opportunity based on facility capacity, scale, location and infrastructure. Subject to regulatory approval, among other things, and may change based on design considerations, regulatory review process, engagement with contractors and other factors. Figures are rounded.

 

10


Table of Contents
   

Vertical Integration and Opportunistic Investment

 

   

In addition to our core business, our liquefaction and export projects, we regularly evaluate complementary businesses that have the potential to strengthen our vertical integration, drive growth and support margin expansion. We have already engaged in substantial activities to establish complementary gas transportation, LNG tanker and regasification business lines that we plan to leverage in connection with our core assets.

 

   

Beyond our LNG facilities under development, the bolt-on expansions, and complementary businesses described above, we consistently explore opportunities, both domestic and international, to develop or acquire other LNG projects and further grow our footprint. We believe our design and approach are adaptable and exportable, providing us ample opportunities, both domestically and internationally, beyond our current development pipeline.

 

LOGO

Risk Factors

Before you invest in our Class A common stock, you should carefully consider all the information in this prospectus, including the risks associated with our business and this offering set forth under the heading “Risk Factors.” These risks include, among others:

 

   

Our ability to maintain profitability and positive operating cash flows is subject to significant uncertainty.

 

   

We have only a limited track record and historical financial information, and there is no assurance that our business will be successful over the long term.

 

   

Our ability to generate proceeds from sales of commissioning cargos is subject to significant uncertainty and volatility in such proceeds. Historical proceeds from such sales at the Calcasieu Project, which has had an extended commissioning period due to unanticipated challenges with equipment reliability that we are in the process of remediating, may not be indicative of the duration of the commissioning period or the amount of proceeds for any future period or for any of our other projects.

 

   

We have not entered into SPAs with customers for the total expected nameplate capacity at the CP2 Project, the CP3 Project or the Delta Project and our failure to enter into final and binding contracts for an adequate portion or any of, or to otherwise sell, the expected nameplate capacity of any of our projects, could have a material adverse effect on our prospects.

 

   

Our revenues and operating margins may be adversely affected if we are unable to produce and sell liquefaction capacity in excess of the nameplate capacity of our facilities.

 

   

Our customers or we may terminate our SPAs if certain conditions are not met or for other reasons.

 

   

Our ability to generate cash under our post-COD SPAs is substantially dependent upon the performance by a limited number of our customers, and we could be materially and adversely affected if certain of these customers fail to perform their contractual obligations for any reason.

 

11


Table of Contents
   

Our operating margins may be adversely affected if the price of natural gas decreases, if we pay a premium for feed gas relative to the contractual spot price we charge our customers, or as a result of inflationary pressures.

 

   

We may not be able to purchase or receive physical delivery of sufficient natural gas to satisfy our delivery obligations under the SPAs, which could have a material adverse effect on us.

 

   

Our limited diversification could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

 

   

We are dependent on the strategic direction of Michael Sabel, our Chief Executive Officer, Executive Co-Chairman and Founder, and Robert Pender, our Executive Co-Chairman and Executive Co-Chairman of the Board and Founder.

 

   

We and our contractors, including our EPC contractors, may experience increased labor costs, and the unavailability of skilled workers or our failure to attract and retain qualified personnel could adversely affect us.

 

   

We will require significant additional capital to construct and complete certain of our projects, and we may not be able to secure such financing on time with acceptable terms, or at all, which could cause delays in our construction, lead to inadequate liquidity and increase overall costs.

 

   

We may not construct or operate all of our proposed LNG facilities or pipelines or any additional LNG facilities or pipelines beyond those currently planned, and we may not pursue some or any of the bolt-on expansion opportunities we have identified at our current projects, which could limit our growth prospects.

 

   

We are dependent on our contractors for the successful completion of our projects and any bolt-on expansion opportunities at our projects that we may pursue, and any failure by our contractors to perform their contractual obligations could have a material adverse impact on our projects.

 

   

We have not entered into all of the definitive agreements for the CP2 Project, the CP3 Project or the Delta Project and there can be no assurance that we will be able to do so on a timely basis or on terms that are acceptable to us.

 

   

Certain of our contractual arrangements relating to development and construction of our projects include termination rights that, if exercised, could have a material adverse impact on our projects.

 

   

Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.

 

   

Delays in the construction of our projects beyond the estimated development periods could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

 

   

Our business could be materially and adversely affected if we do not secure the right or if we lose the right to situate certain lateral pipelines, longer-haul pipelines or any other pipeline infrastructure for any of our projects on property owned by third parties, or if we do not complete the construction of those pipelines in a timely fashion.

 

   

The natural gas liquefaction system and mid-scale, factory-fabricated design we utilize at our projects are the first of such sized modules developed by us and Baker Hughes, and there can be no assurance that these modules, or our projects, will achieve the level of performance or other benefits that we anticipate over the long term.

 

   

Competition in the LNG industry is intense, and certain of our competitors may have greater financial, engineering, marketing and other resources than we have.

 

12


Table of Contents
   

We face competition based upon the international market price for LNG.

 

   

Servicing our indebtedness and preferred equity will require a significant amount of cash and we may not have sufficient cash, operating cash flows and capital resources to service our existing and future indebtedness and preferred equity.

 

   

We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.

 

   

If we are unsuccessful in our current and any potential future arbitration proceedings with our customers, the amounts that we are required to pay may be substantial and certain of our post-COD SPAs may be terminated, which may lead to an acceleration of all our debt for the relevant project.

 

   

VG Partners will continue to have significant influence over us after this offering, including control over decisions that require their approval, which could limit your ability to influence the outcome of key transactions, including a change of control.

 

   

An active, liquid trading market for our Class A common stock may not develop or be sustained, and there is the possibility of significant fluctuations in the price of our Class A common stock

 

   

We cannot guarantee that we will pay further dividends on our Class A common stock in the future and, consequently, your ability to achieve a return on your investment will depend on appreciation in the price of our Class A common stock.

For a discussion of these and other risks, see “Risk Factors.”

Our Founders

Robert Pender and Michael Sabel, our founders, control Venture Global Partners II, LLC, or VG Partners, which is our controlling stockholder. Prior to this offering, VG Partners owned approximately 84% of all series of our common stock outstanding and, upon consummation of this offering, VG Partners will own 100% of our outstanding Class B common stock. Class B common stock will represent approximately  % of the total combined voting power of our outstanding common stock following this offering (or approximately  % of the total combined voting power of our outstanding common stock if the underwriters exercise in full their option to purchase additional shares of our Class A common stock).

Corporate Information

Our direct subsidiary, VGLNG, which owns all of our subsidiaries, was originally established in 2013 by our founders. As part of certain corporate reorganization transactions, or Reorganization Transactions, Venture Global, Inc. was formed in 2023 and became the 100% owner of VGLNG. For more information about the Reorganization Transactions, see “Certain Relationships and Related Party Transactions—Reorganization Transactions.”

We are a holding company and have no direct operations. All of our business operations are conducted through our subsidiaries, including VGLNG. Our principal asset is the equity interest in VGLNG, which, together with its subsidiaries, owns substantially all of our operating assets. As a result, we are dependent on the ability of our subsidiaries to generate revenues and to make loans, pay dividends and make other payments to generate the funds necessary to meet our financial obligations and to pay dividends to stockholders, if any. The below chart illustrates our current corporate organizational structure immediately after consummation of this offering.

 

13


Table of Contents

 

LOGO

 

Notes:

 

(1)

Simplified organizational chart that does not include all legal entities. All ownership is 100% of the existing common equity of each entity listed unless otherwise noted.

(2)

The ownership of VGLNG includes three million shares of its 9.00% Series A Fixed-Rate Reset Cumulative Redeemable Perpetual Preferred Stock, with a $1,000 liquidation preference per share, or the VGLNG Series A Preferred Shares, that entitles holders to receive, when and if declared by VGLNG’s board of directors, cumulative, semi-annual cash dividends at a rate of 9.00% per annum of the $1,000 liquidation preference per share. The dividend rate will reset in accordance with the terms of the VGLNG Series A Preferred Shares. For more detail, see “Description of Material Financing—VGLNG Equity Financing—VGLNG Series A Preferred Shares.”

(3)

The ownership of Calcasieu Pass Funding, LLC includes a redeemable preferred equity investment by a third party fund associated with Stonepeak Infrastructure Partners, or Stonepeak Fund II, of certain redeemable preferred units that entitles Stonepeak Fund II to certain distributions on its investment, either in the form of permitted cash distributions from available cash at Calcasieu Pass Funding, LLC or accrued distributions on the funding face value of the preferred units. As of September 30, 2024, we owned 100% of all the outstanding common units of Calcasieu Pass Funding, LLC, while Stonepeak Fund II owned 100% of all of the outstanding redeemable preferred units of Calcasieu Pass Funding, LLC. As of September 30, 2024, the aggregate outstanding amount of the redeemable preferred units was $1.5 billion. For more detail, see “Description of Material Financing—Project Equity Financing—Calcasieu Pass Funding, LLC Preferred Units.”

(4)

The ownership of Calcasieu Pass Holdings, LLC includes a convertible preferred equity investment by a third party fund associated with Stonepeak Infrastructure Partners, or Stonepeak Fund I, of certain convertible preferred units that entitles Stonepeak Fund I to certain distributions in kind in the form of additional preferred units or in cash (as elected by Calcasieu Pass Holdings, LLC), in the form of additional preferred units. Upon the occurrence of certain conditions, the convertible preferred units are expected to automatically convert to a number of Class B common units of Calcasieu Pass Holdings, LLC. Assuming that we service all future distributions on the Holdings Preferred Units until the commencement of COD in cash, such preferred units are expected to convert into approximately 23% of the common units of Calcasieu Pass Holdings, LLC. For more detail, see “Description of Material Financing—Project Equity Financing—Calcasieu Pass Holdings, LLC Preferred Units.”

For more information about the risks of investing in a holding company, see our “Risk Factors” elsewhere in this prospectus.

 

14


Table of Contents

Our principal executive offices are located at 1001 19th Street North, Suite 1500, Arlington, VA, 22209, and our telephone number is (202) 759-6740. Our internet address is www.ventureglobal.com. Our website, information on our website or any other website is not incorporated by reference in this prospectus and is included in this prospectus as an inactive textual reference only.

 

15


Table of Contents

THE OFFERING

 

Issuer

Venture Global, Inc.

 

Class A common stock offered by us

     shares

 

Option by the underwriters to purchase additional shares of Class A common stock

     shares

 

Class A common stock to be outstanding after this offering

     shares (or     shares if the underwriters exercise in full their option to purchase additional shares)

 

Class B common stock to be outstanding after this offering

     shares. In connection with the consummation of this offering, Class A common stock held by VG Partners immediately prior thereto will convert into an equal number of shares of Class B common stock.

 

Use of proceeds

We estimate that the net proceeds to us from the sale of our Class A common stock in this offering will be approximately $    billion, or approximately $    billion if the underwriters exercise their option to purchase additional shares in full, assuming an initial public offering price of $    per share (the midpoint of the range set forth on the cover page of this prospectus), after deducting estimated underwriting discounts and commissions and estimated offering expenses.

 

  Each $1.00 increase (decrease) in the public offering price per share would increase (decrease) our net proceeds, after deducting estimated underwriting discounts and commissions, by $    million (assuming the number of shares of our Class A common stock offered by us, as set forth on the cover of this prospectus, remains the same, and assuming no exercise of the underwriters’ option to purchase additional shares). We may also increase or decrease the number of shares we are offering. An increase (decrease) of one million shares in the number of shares of our Class A common stock offered by us would increase (decrease) our net proceeds, after deducting estimated underwriting discounts and commissions, by $    million (assuming the public offering price remains the same, and assuming no exercise of the underwriters’ option to purchase additional shares).

 

 

The principal purposes of this offering are to support the continued growth and development of our business, increase our financial flexibility and establish a public market for our Class A common stock. We intend to use the net proceeds from this offering for general corporate purposes, including, but not limited to, funding our expected pre-FID capital expenditures with respect to the CP2 Project, the CP3 Project and the Delta Project, our continuing operations, our LNG tanker milestone payments, and our pipeline development projects. The intended use of net proceeds from this offering represents our intentions based upon our present plans and business conditions. However, we have no current specific plan with

 

16


Table of Contents
 

regard to the amount of proceeds we will spend on the intended uses set forth above, nor can we predict with certainty all of the particular uses for the proceeds of this offering. Accordingly, our management will have broad discretion in applying the net proceeds of this offering. See “Use of Proceeds” for more information.

 

Voting rights

Upon completion of this offering, we will have two classes of voting common stock, Class A common stock and Class B common stock.

 

  Shares of our Class A common stock are entitled to one vote per share.

 

  Shares of our Class B common stock are entitled to 10 votes per share.

 

  Holders of Class A common stock and Class B common stock will vote together as a single class on all matters (including the election of directors) submitted to a vote of stockholders, except as otherwise provided in our amended and restated certificate of incorporation or as required by applicable law. See “Description of Capital Stock.”

 

Conversion rights

Shares of our Class A common stock are not convertible into any other class of shares.

 

  Shares of our Class B common stock are convertible into shares of our Class A common stock on a one-for-one basis at the option of the holder. In addition, each share of Class B common stock will convert automatically into one fully paid and nonassessable share of Class A common stock upon any transfer of such share, except for certain permitted transfers described in our amended and restated certificate of incorporation. See “Description of Capital Stock—Common Stock—Conversion, Exchange and Transferability.”

 

Concentration of control

Upon completion of this offering, VG Partners will beneficially own all outstanding shares of Class B common stock, representing    % of the total combined voting power of our outstanding common stock (or    % of the total combined voting power of our outstanding common stock if the underwriters exercise their option to purchase additional shares in full). Accordingly, we will be a “controlled company” under the corporate governance rules of the NYSE, and VG Partners will have the ability to control the outcome of matters submitted to our stockholders for approval, including the election of our directors and the approval of any change in control transaction. See “Principal Stockholders” and “Description of Capital Stock—Common Stock—Voting Rights.”

 

Risk factors

You should carefully read and consider the information set forth in the section entitled “Risk Factors” beginning on page 22, together with all of the other information set forth in this prospectus, before deciding whether to invest in our Class A common stock.

 

Proposed stock exchange symbol

We have applied to list our Class A common stock on the NYSE under the symbol “VG.”

The audited consolidated financial statements and unaudited condensed consolidated financial statements and related notes to those statements included elsewhere in this prospectus, have not been adjusted for the Stock

 

17


Table of Contents

Split, which will be effectuated after the effectiveness of the registration statement of which this prospectus forms a part and before the completion of this offering. Unless otherwise indicated, all other share and per share data in this prospectus have been retroactively adjusted, where applicable, to reflect the Stock Split as if it had occurred at the beginning of the earliest period presented.

The number of shares of Class A common stock that will be outstanding after this offering is based on    shares of Class A common stock outstanding as of    , 2024, and gives effect to the Stock Split and the automatic conversion of all shares of Class A common stock held immediately prior to the completion of this offering by VG Partners into     shares of our Class B common stock, which will occur immediately after the Stock Split and immediately prior to the completion of this offering, but excludes:

 

   

   shares of Class A common stock issuable on the exercise of stock options outstanding as of    , 2024 under the Amended and Restated Venture Global, Inc. 2023 Stock Option Plan, or the 2023 Plan, with a weighted-average exercise price of $    per share (after giving effect to the Stock Split);

 

   

   shares of Class A common stock reserved for future issuance under our new omnibus incentive plan adopted in connection with this offering, or the 2024 Plan, as well as any future increases, including annual automatic evergreen increases, in the number of shares of Class A common stock reserved for issuance under our 2024 Plan, of which stock options representing approximately    shares of Class A common stock issuable upon exercise will be granted in connection with this offering to certain of our employees with an exercise price per share equal to the initial public offering price, or the IPO Grants; and

 

   

   shares of Class A common stock reserved for future issuance upon the exchange of    shares of Class B common stock on a one-for-one basis.

The number of shares of Class B common stock that will be outstanding after this offering is based on the automatic conversion of all shares of Class A common stock held immediately prior to the completion of this offering by VG Partners into     shares of our Class B common stock, which will occur immediately after the Stock Split and immediately prior to the completion of this offering.

Except as otherwise indicated, all information in this prospectus assumes:

 

   

an initial public offering price of $    per share, which is the midpoint of the estimated public offering price range set forth on the cover page of this prospectus;

 

   

the filing and effectiveness of our amended and restated certificate of incorporation, which will occur immediately prior to the completion of this offering, and the effectiveness of our amended and restated bylaws, which will occur immediately following completion of this offering;

 

   

except in the case of the audited consolidated financial statements and unaudited consolidated financial statements and related notes to those statements included elsewhere in this prospectus, the Stock Split, which will occur immediately prior to the automatic conversion of certain shares of Class A common stock described in the following bullet;

 

   

the automatic conversion of all shares of Class A common stock held immediately prior to the completion of this offering by VG Partners into     shares of our Class B common stock, which will occur immediately after the Stock Split and immediately prior to the completion of this offering; and

 

   

no exercise of the underwriters’ option to purchase up to    additional shares of Class A common stock from us in this offering.

 

18


Table of Contents

SUMMARY CONSOLIDATED FINANCIAL AND OTHER DATA

The following summary consolidated financial data of the Company should be read in conjunction with, and are qualified by reference to, the information under “Management’s Discussion and Analysis of Financial Condition and Results of Operations” and the consolidated financial statements and notes thereto included elsewhere in this prospectus. The summary consolidated statement of income data for the years ended December 31, 2023, 2022 and 2021, and the consolidated balance sheet data as of December 31, 2023 and 2022, are derived from, and qualified by reference to, the audited consolidated financial statements of the Company included elsewhere in this prospectus, and should be read in conjunction with those consolidated financial statements and notes thereto. The summary consolidated data for the nine months ended September 30, 2024 and 2023, and the balance sheet data as of September 30, 2024, are derived from, and qualified by reference to, the unaudited condensed consolidated financial statements of the Company included elsewhere this prospectus. The unaudited condensed consolidated financial statements of the Company included elsewhere this prospectus have been prepared on the same basis as the audited consolidated financial statements of the Company included elsewhere this prospectus and reflect, in the opinion of management of the Company, all adjustments of a normal, recurring nature that are necessary for a fair presentation of the unaudited condensed consolidated financial statements. Our historical results are not necessarily indicative of our future results, and our interim results are not necessarily indicative of our future results to be expected for a full fiscal year or any other interim period. The summary financial data in this section are not intended to replace our financial statements and related notes appearing at the end of this prospectus.

 

     Nine months ended
September 30,
    Year Ended December 31,  
     2024     2023     2023     2022     2021  
     (in millions, except share and per share data)  

Statement of Operations Data:

          

Revenue

   $ 3,448     $ 6,265     $ 7,897     $ 6,448     $ —   

Operating expense:

          

Cost of sales (exclusive of depreciation and amortization shown separately below)

     937       1,195       1,684       2,093       —   

Operating and maintenance expense

     378       279       391       140       58  

General and administrative

     224       165       224       191       89  

Development expense

     511       324       490       311       188  

Depreciation and amortization

     229       208       277       158       6  

Insurance recoveries, net of loss from hurricane

     —        (19     (19     —        (4
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Total operating expenses

     2,279       2,152       3,047       2,893       337  
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Income (loss) from operations

     1,169       4,113       4,850       3,555       (337
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Other income (expense):

          

Interest income

     187       103       172       18       —   

Interest expense, net

     (467     (448     (641     (592     (52

Gain on derivatives, net

     70       830       174       1,212       38  

Gain (loss) on embedded derivative

     —        —        —        (14     12  

Loss on financing transactions

     (14     (113     (123     (635     (97
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Total other income (expense)

     (224     372       (418     (11     (99
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Income (loss) before income tax expense

     945       4,485       4,432       3,544       (436
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Income tax expense

     189       868       816       447       —   
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income (loss)

     756       3,617       3,616       3,097       (436
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

 

19


Table of Contents
     Nine months ended
September 30,
    Year Ended December 31,  
     2024     2023     2023     2022     2021  
     (in millions, except share and per share data)  

Less: Net income attributable to redeemable stock of subsidiary

   $ 107     $ 96     $ 130     $ 118     $ 107  

Less: Net income (loss) attributable to non-controlling interests

     44       790       805       1,121       (187

Less: Dividends on VGLNG Series A Preferred Shares

     1       —        —        —        —   
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income (loss) attributable to stockholders and members

   $ 604     $ 2,731     $ 2,681     $ 1,858     $ (356
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Earnings per share:

          

Basic earnings (loss) per share

          

Net income (loss) attributable to common stockholders per share—basic

   $ 1,162     $ 6,249     $ 5,855     $ 4,266     $ (817

Weighted average number of shares of common stock outstanding—basic

     519,772       437,043       457,896       435,500       435,500  

Diluted earnings (loss) per share

          

Net income (loss) attributable to common stockholders per share—diluted

   $ 1,060     $ 6,232     $ 5,656     $ 4,266     $ (817

Weighted average number of shares of common stock outstanding—diluted

     570,022       438,237       474,033       435,500       435,500  

Pro forma basic earnings (loss) per share(1)

          

Net income (loss) attributable to common stockholders per share—basic

   $       $       $       $       $    

Weighted average number of shares of common stock outstanding—basic

          

Pro forma diluted earnings (loss) per share(1)

          

Net income (loss) attributable to common stockholders per share—diluted

   $       $       $       $       $    

Weighted average number of shares of common stock outstanding—diluted

          

Cash flow data:

          

Net cash from (used by) operating activities

   $ 1,476     $ 3,957     $ 4,550     $  3,702     $ (503

Net cash used by investing activities

     (10,436     (5,044     (8,725     (2,900     (2,078

Net cash from financing activities

     8,723       1,793        7,635       235        3,623  

Segment income (loss) from operations:

          

Calcasieu Pass Project

   $ 2,066     $ 4,625     $ 5,598     $ 4,042     $ (85

Plaquemines Project

     (163     (132     (187     (269     (158

CP2 LNG Project

     (396     (233     (362     (34     (15

Corporate, other and eliminations(2)

     (338     (147     (199     (184     (79
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Total

   $ 1,169     $ 4,113     $ 4,850     $ 3,555     $ (337
  

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

 

(1)

We compute pro forma basic and diluted earnings (loss) per share as if the Stock Split had occurred at the beginning of the earliest period presented. Pro forma basic earnings (loss) per share is computed using net income (loss) attributable to common stockholders divided by the weighted average number of shares of common stock outstanding during the period. Weighted average number of shares of common stock

 

20


Table of Contents
  outstanding reflects the Stock Split. Pro forma diluted earnings (loss) per share is computed using the weighted average number of shares of common stock and the effect of potentially dilutive equity awards outstanding during the period.

 

(2)

Includes costs associated with the CP3 Project, the Delta Project, certain other development stage projects, our shipping business, certain corporate activities, and eliminations.

 

     As of  
     September 30,
2024
     December 31,
2023
     December 31,
2022
 
     (in millions)  

Balance Sheet Data:

        

Cash and cash equivalents

   $ 4,562      $ 4,823      $ 618  

Total assets

     39,423        28,463        15,097  
  

 

 

    

 

 

    

 

 

 

Total liabilities

     32,504        24,993        13,333  
  

 

 

    

 

 

    

 

 

 

Total stockholders’ equity

   $ 5,427      $ 2,085      $ 509  
  

 

 

    

 

 

    

 

 

 

 

21


Table of Contents

RISK FACTORS

An investment in our Class A common stock involves a high degree of risk. You should carefully consider the risks and uncertainties described below, together with all other information contained in this prospectus, before making an investment in our Class A common stock. If any of the following risks were to occur, our business, financial condition, results of operations and cash flow could be materially adversely affected. In that case, the trading price of our Class A common stock could decline, and you could lose all or part of your investment.

The following risks are not the only ones facing our company. Additional risks and uncertainties not currently known to us, or that we currently deem immaterial, may also impair or adversely affect us. You are strongly encouraged to consult your own professional advisors (including tax and regulatory) before deciding to invest in our Class A common stock.

Risks Relating to Our Business

Our ability to maintain profitability and positive operating cash flows is subject to significant uncertainty.

We will continue to incur significant capital and operating expenditures while we develop, construct, and commission our projects. Our ability to maintain profitability and positive operating cash flows is primarily dependent on our ability to generate proceeds, and in turn net profits and operating cash flows, through the sale of LNG commissioning cargos, the sale of excess LNG that is produced above the nameplate capacity of our LNG projects, and, after COD occurs for a given project, through the sale of LNG pursuant to our post-COD SPAs, as well as our ability to monetize our other assets (such as pipelines, LNG tankers and downstream regasification capacity).

Our ability to sell LNG commissioning cargos depends on our ability to successfully market, produce, load and, in some cases, deliver commissioning cargos during the commissioning of each of our projects prior to achieving COD. Although we have generated proceeds from the sales of commissioning cargos at the Calcasieu Project since the first quarter of 2022 and we expect to do so at each of our other projects during commissioning, prior to the relevant COD, such sales of commissioning cargos are limited in duration and subject to a number of material uncertainties and risks. In addition, we are obligated to cease sales of commissioning cargos once the relevant COD occurs. As a result, the duration of the commissioning period at the Calcasieu Project, which has been extended by a force majeure event, and the amount of proceeds we have generated from the sales of commissioning cargos from the Calcasieu Project to date may not be indicative of the duration of the commissioning period or the amount of proceeds from such sales for any future period for the Calcasieu Project or for any of our other projects. See “—Our ability to generate proceeds from sales of commissioning cargos is subject to significant uncertainty and volatility in such proceeds. Historical proceeds from such sales at the Calcasieu Project, which has had an extended commissioning period due to unanticipated challenges with equipment reliability that we are in the process of remediating, may not be indicative of the duration of the commissioning period or the amount of the proceeds for any future period or for any of our other projects” and “Business—Our Liquefaction and Export Projects and Key, Complementary Assets—Calcasieu Project.”

Our ability to generate sales of LNG following COD at each of our projects depends on our ability to successfully commence and maintain deliveries under our post-COD SPAs. Such revenues can be further supplemented if we are able to produce and sell LNG in excess of the nameplate capacity of our projects. We will not generate any revenues or operating cash flow under our post-COD SPAs (including the six 20-year LNG sale and purchase agreements for the Calcasieu Project, or the Calcasieu Foundation SPAs), or from sales to third parties of excess LNG until we have achieved COD for the relevant project. We are currently targeting a COD for the Calcasieu Project at the end of March 2025 and a COD for the Plaquemines Project in the third quarter of 2026 for Phase 1 and the second quarter of 2027 for Phase 2. Assuming timely receipt of required regulatory approvals, COD for the CP2 Project is currently targeted to occur in mid-2029 for Phase 1 and mid-2030 for

 

22


Table of Contents

Phase 2. The CP3 Project and the Delta Project are still in early stages of development. Assuming timely receipt of required regulatory approvals and certain other factors, COD for the CP3 Project is currently targeted to occur in mid-2031 for Phase 1 and mid-2032 for Phase 2 and COD for the Delta Project is currently targeted to occur in mid-2033 for Phase 1 and mid-2034 for Phase 2. However, there is no guarantee that we will achieve such CODs within those timeframes or at all. See “—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

As a result, there can be no assurance as to when we will commence deliveries under our post-COD SPAs, and therefore when, if at all, we will commence generating revenues and operating cash flows from our post-COD SPAs or from the sale of LNG produced in excess of nameplate capacity, if any, for the Calcasieu Project or any of our other projects. In addition, there can be no assurance that we will be able to produce excess LNG above the nameplate capacity of the facilities at our projects, either at our target level of excess LNG production or at all, nor, even if such excess LNG is produced, that we will be able to resell all of it to third party customers.

Our ability to monetize our other assets, including our pipelines, LNG tankers and regasification facility capacity depends on a variety of factors, including but not limited to market conditions in the natural gas and LNG industries, required regulatory and governmental approvals, and our ability to successfully market, produce, load and deliver commissioning cargos during the commissioning of each of our projects prior to achieving COD and our ability to generate sales of LNG following COD at each of our projects. Specifically, our ability to construct and successfully monetize our interstate and intrastate pipelines will depend, among other factors, on worldwide demand for LNG, as well as on our obtaining the necessary regulatory approvals for our projects currently under development. Additionally, while we expect several of our LNG tankers to service our single DPU post-COD SPA, our ability to monetize the remainder of our LNG tanker fleet will depend on the demand from LNG customers or, potentially, other charterers, as well as that from any future SPAs we may enter into where LNG is sold on a delivered basis, for the services of such LNG tankers. Our ability to monetize the regasification facility capacity we have secured through our agreements with Grain LNG and the Alexandroupolis LNG receiving terminals will depend on demand for both LNG and regasified natural gas from downstream customers in the UK and European markets.

As a result, there is significant uncertainty about our ability to maintain profitability and positive operating cash flows.

We have only a limited track record and historical financial information, and there is no assurance that our business will be successful over the long term.

Prior to July 2014, we conducted no business or operations and we recorded no revenues or expenses. We first generated proceeds from sales of commissioning cargos at the Calcasieu Project only in the first quarter of 2022, and prior to that we incurred significant losses from operations and negative cash flows from operations.

Our activities to date have included organizational efforts related to the development and construction of our projects and related assets, including but not limited to:

 

   

raising capital;

 

   

securing options to lease and leasing our project sites;

 

   

negotiating and planning with various contractors for the development and production of such sites;

 

   

negotiating SPAs with purchasers;

 

   

negotiating and entering into construction contracts with construction contractors; and

 

   

procuring gas transportation and supply.

 

23


Table of Contents

In addition, the proceeds we have generated to date are solely proceeds generated from sales of commissioning cargos from the Calcasieu Project, may not be indicative of the duration of the commissioning period or the amount of proceeds from such sales for any future period for the Calcasieu Project or for any of our other projects, or of our future results of operations more generally. See “—Our ability to generate proceeds from sales of commissioning cargos is subject to significant uncertainty and volatility in such proceeds. Historical proceeds from such sales at the Calcasieu Project, which has had an extended commissioning period due to unanticipated challenges with equipment reliability that we are in the process of remediating, may not be indicative of the duration of the commissioning period or the amount of proceeds for any future period or for any of our other projects.”

Our limited operating history may limit your ability to evaluate our prospects because of our limited historical financial data, our unproven ability to maintain or increase our profitability and our limited experience in addressing issues that may affect our ability to manage the construction, operation or maintenance of liquefaction facilities and related assets. We face all of the risks commonly encountered by other growing businesses, including competition and the need for additional capital and personnel. As a result, any assessment you make about our current business and any predictions you make about our future success or viability may not be accurate. There is no assurance that our business will be successful over the long term.

Our ability to generate proceeds from sales of commissioning cargos is subject to significant uncertainty and volatility in such proceeds. Historical proceeds from such sales at the Calcasieu Project, which has had an extended commissioning period due to unanticipated challenges with equipment reliability that we are in the process of remediating, may not be indicative of the duration of the commissioning period or the amount of proceeds for any future period or for any of our other projects.

A key element of our business strategy is to generate proceeds from the sale of LNG at each of our projects during the commissioning phases of our projects, prior to the relevant project achieving COD.

The duration of the commissioning period and our ability to generate such proceeds is subject to significant risks and uncertainties relating to the development, construction and commissioning of our projects as discussed in these “Risk Factors.” In particular, it is both our intention and our obligation, under our post-COD SPAs, to undertake the construction of and complete our projects or phases thereof in a reasonable and prudent manner, which, depending on the circumstances, could extend or shorten the commissioning period for such projects or phases thereof during which we are able to generate such proceeds. Further, certain delays in the development of or construction of our projects, and any issues with the construction of our projects could delay or otherwise adversely impact our ability to generate such proceeds during the commissioning of the relevant projects. At any of our projects or phases thereof, if the commissioning of certain equipment or integrated facilities is delayed or if COD occurs earlier than expected, the duration of time when we are able to generate proceeds from the sale of commissioning cargos may be shortened, which could adversely impact the volume of LNG produced during commissioning and our ability to generate proceeds from the sale of commissioning cargos.

Historical proceeds from the sale of commissioning cargos at the Calcasieu Project, which has had an extended commissioning period due to unanticipated challenges with equipment reliability that we are in the process of remediating, may not be indicative of the duration of the commissioning period or the amount of proceeds for any future period or for any of our other projects. See “Business—Our Liquefaction and Export Projects and Key, Complementary Assets—Calcasieu Project.” Although we have included targeted COD dates for our projects and phases thereof, there can be no assurance that COD will not occur earlier or later than such targets. See “Business—Our Liquefaction and Export Projects and Key, Complementary Assets.” If COD occurs earlier than expected for a particular project or phase thereof, it would adversely impact our ability to generate proceeds from the sale of commissioning cargos, which, subject to market conditions, may otherwise be more valuable than the revenues earned under our post-COD SPAs.

 

24


Table of Contents

In addition to the duration of the commissioning period, our ability to generate such proceeds depends on our ability to negotiate sales during the construction and commissioning phases of each project. There is no assurance that we will be able to continue to successfully negotiate sales of such commissioning cargos on terms that are acceptable to us, or that we will be able to successfully market, produce, load and deliver such commissioning cargos, either from the Calcasieu Project or any other project, in the future. In addition, because commissioning cargos are not sold under post-COD SPAs and are instead sold on varying terms, including in some instances on a forward basis, proceeds from such commissioning cargos may vary significantly depending on, among other factors, prices and market conditions in the international LNG markets, global LNG freight rates, and on the timing of when a contract for sale is executed. As such, the amount of any proceeds that we may generate from the sale of commissioning cargos and our profitability relating to such sales is largely dependent on the strength of international LNG markets, as primarily reflected in the spot price for LNG at the time a contract for sale of commissioning cargos is executed. Historically, the spot price for LNG has varied significantly, which has impacted the amount of proceeds we have generated. For example, the average month-end spot price for U.S. Gulf Coast LNG decreased from $16.38/MMBtu in the first quarter of 2023, to $7.45/MMBtu in the first quarter of 2024. During the same period, the gross proceeds we received from sales of commissioning cargos from the Calcasieu Project decreased from $2.9 billion ($2.4 billion in net proceeds after deducting net cash paid for natural gas, which primarily includes the net cost of purchasing and transporting feed gas) for the three month period ended March 31, 2023, to $1.4 billion ($1.0 billion in net proceeds, after deducting net cash paid for natural gas) for the three month period ended March 31, 2024. See “—Risks Relating to the LNG Industry—We face competition based upon the international market price for LNG” and “—Risks Relating to the LNG Industry—Cyclical or other changes in the demand for and price of LNG and natural gas may adversely affect our business and the performance of our customers and could have a material adverse effect on our business, contracts, financial condition, operating results, cash flows, liquidity and prospects and the price of our Class A common stock.”

We may at times contract commissioning cargos on a forward basis and, as a result, these sales of commissioning cargos may be uncorrelated with movements in spot LNG prices. For example, the average month-end spot price for U.S. Gulf Coast LNG increased from $8.60/MMBtu in the second quarter of 2023, to $8.61/MMBtu in the second quarter of 2024. During the same period, however, the gross proceeds we received from sales of commissioning cargos from the Calcasieu Project decreased from $2.2 billion ($1.9 billion in net proceeds, after deducting net cash paid for natural gas) for the three months ended June 30, 2023, to $1.2 billion ($0.9 billion in net proceeds, after deducting net cash paid for natural gas) for the three months ended June 30, 2024.

As a result, we have experienced, and expect to continue to experience during the remainder of the commissioning phase, significant volatility in the proceeds we have generated from the sales of commissioning cargos from the Calcasieu Project. Since we began generating proceeds from the sale of commissioning cargos in the first quarter of 2022, our quarterly gross proceeds have fluctuated from a maximum of $2.9 billion ($2.4 billion in net proceeds, after deducting net cash paid for natural gas) for the three months ended March 31, 2023, to a minimum of $1.0 billion ($0.7 billion in net proceeds, after deducting net cash paid for natural gas) for the three months ended September 30, 2023. Accordingly, the proceeds we have generated from such sales of commissioning cargos of the Calcasieu Project to date may not be indicative of the duration of the commissioning period or the amount of proceeds from such sales for any future period for the Calcasieu Project or for any of our other projects. As a result, such proceeds, and also our operating results more generally, may vary significantly from one fiscal period to the next comparable fiscal period. Moreover, if we are not able to generate proceeds from the sale of commissioning cargos in the future that are comparable to such proceeds from the Calcasieu Project in the past, that could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

 

25


Table of Contents

Our ability to optimize sales of post-COD LNG cargos is subject to significant uncertainty and volatility in proceeds generated from such sales.

Our business strategy includes recycling cash proceeds from one project to fund our subsequent projects in order to reduce our need for a critical mass of long-term post-COD SPAs for such future projects. That strategy, in turn, is intended to allow us to optimize sales of LNG produced following COD. In particular, production capacity from our projects that is not otherwise committed can be sold on a short-, medium- or long-term basis, including on a spot basis, which can provide flexibility to optimize the pricing for such capacity and can help us balance profit, duration and risk.

Our ability to optimize sales of LNG cargos that are not otherwise committed will depend on our ability to negotiate sales that meet our objective of balancing profit, duration and risk. There is no assurance that we will be able to successfully negotiate sales of such cargos on terms that are acceptable to us. In addition, because such cargos may be sold on varying terms, including in some instances on a forward basis, proceeds from such cargos may vary significantly from period-to-period and from project-to-project depending on, among other factors, prices and market conditions in the international LNG markets, global LNG freight rates, and on the timing of when a contract for sale is executed. Further, the amount of any proceeds that we may generate from such sales, and our profitability relating to such sales, is largely dependent on the strength of international LNG markets, as primarily reflected in the spot price for LNG at the time a contract for sale of such cargos is executed. Historically, the spot price for LNG has varied significantly, and we expect the spot price will continue to vary significantly in the future which will impact the amount of proceeds we generate from such sales. For example, the average month-end spot price for U.S. Gulf Coast LNG decreased from $16.38/MMBtu in the first quarter of 2023, to $7.45/MMBtu in the first quarter of 2024. See “—Risks Relating to the LNG Industry—We face competition based upon the international market price for LNG” and “—Risks Relating to the LNG Industry—Cyclical or other changes in the demand for and price of LNG and natural gas may adversely affect our business and the performance of our customers and could have a material adverse effect on our business, contracts, financial condition, operating results, cash flows, liquidity and prospects and the price of our Class A common stock.” Further, we may at times contract such cargos on a forward basis and, as a result, such sales may be uncorrelated with movements in spot LNG prices.

As a result, we may experience significant volatility in any proceeds we generate from sales of post-COD LNG cargos at future projects, in particular if we reduce the proportion of such cargos that are committed under long-term SPAs. Moreover, if we are not able to effectively optimize sales of such cargos in the future, that could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We have not entered into SPAs with customers for the total expected nameplate capacity at the CP2 Project, the CP3 Project or the Delta Project, and our failure to enter into final and binding contracts for an adequate portion of, or to otherwise sell, the expected nameplate capacity of any of our projects, could have a material adverse effect on our prospects.

Our ability to generate revenue and cash flow is partially based on our ability to enter into long-term SPAs with customers with respect to the expected nameplate capacity of our projects. Changes in market conditions relating to, among other factors, the price of natural gas in the United States and the price of LNG in international markets could adversely affect the competitiveness of our projects and our ability to enter into such SPAs, which could adversely impact our potential revenues. See “—Risks Relating to the LNG Industry—Failure of LNG exported from the United States, including from our projects, to remain a competitive source of energy for international markets could adversely affect the LNG business of our customers, which could have a material adverse effect on their ability and willingness to perform under their post-COD SPAs with us or otherwise contract with us, and on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.”

We are actively marketing a portion of the remaining expected nameplate capacity of the CP2 Project to leading international oil and gas companies, national and multinational utilities and LNG portfolio trading

 

26


Table of Contents

companies. As of September 30, 2024, the CP2 Project has contracted to sell 9.25 mtpa of LNG under eight 20-year SPAs. The obligation to make LNG available under these post-COD SPAs commences from the occurrence of COD for Phase 1 of the CP2 Project. As of this date, we have not entered into any SPAs for the expected nameplate capacity for the CP3 Project and the Delta Project and have not yet begun actively marketing the expected nameplate capacity for such projects. While taking FID for a given project is subject to numerous factors, we may elect to proceed with FID for the CP2 Project, the CP3 Project or the Delta Project or any other future projects only after we execute binding SPAs for such projects that cover a targeted portion of the applicable nameplate capacity that we consider adequate to support the development and financing of such project. At such projects, we may also choose to retain certain nameplate capacity on a temporarily uncontracted basis, while proceeding with construction activities, which would leave us more exposed to prevailing spot, short-, and medium-term prices during the life of the LNG facilities. To the extent we are unable to sell the targeted portion of the applicable nameplate capacity of any of our projects on a long-term basis and prevailing spot, short-, and medium-term prices are below current projections, our revenues may be adversely impacted, and any such impact could be significant. In addition, we will likely still be required to pay certain of our operating expenses related to the anticipated production of such remaining LNG (such as pipeline transportation costs) without generating any corresponding revenue. If we are unable to enter into long-term contracts with customers for an adequate portion of the expected nameplate capacity at our future development projects, we may not be able to develop such project, raise adequate financing for such project, or realize sufficient cash flows for our business to remain profitable, which would have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Our revenues and operating margins may be adversely affected if we are unable to produce and sell liquefaction capacity in excess of the nameplate capacity of our facilities.

A key element of our business strategy is to generate revenue from the sale of LNG produced at each of our projects in excess of the nameplate capacity of the relevant project after such project achieves COD.

We are required under certain contracts to use our best efforts to construct and maintain LNG facilities capable of producing excess capacity at least equal to 15% of the guaranteed nameplate capacity of each facility. However, we also aim to construct and maintain our LNG facilities to be capable of producing greater excess capacity, in most cases at least 30% of their guaranteed nameplate capacity. Our ability to produce LNG in excess of the nameplate capacity at each of our projects is subject to significant risks and uncertainties relating to the development, construction and commissioning of our projects as discussed in these “Risk Factors.” Although we believe that our design and configuration will enable us to produce excess LNG without incurring material additional operating expenses or requiring additional capital investment, we may encounter additional, unforeseen costs, resulting in either operating expenses or capital investment, that make production of any excess LNG less economic or, potentially, uneconomic. Any increase in our incremental operating expenses or capital investments could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. As a result, there can be no assurance that we will be successful in producing any such excess LNG at any of our projects on a consistent and reliable basis, or at all.

We generally plan to retain flexibility to sell any excess LNG on a spot basis, or on a short-, medium- or long-term basis. Our ability to sell any such LNG will be subject to a number of risks and uncertainties outside our control, and there can be no assurance as to when, or on what terms, we will be able to sell any such excess LNG, if at all. As a result, revenues from the sale of any such excess LNG may vary significantly depending on prices and conditions in the international LNG markets and depending on when a contract for sale is executed, and the terms of those contracts may not always be favorable. See “—We have not entered into SPAs with customers for the total expected nameplate capacity at the CP2 Project, the CP3 Project or the Delta Project, and our failure to enter into final and binding contracts for an adequate portion of, or to otherwise sell, the expected nameplate capacity of any of our projects, could have a material adverse effect on our prospects” for an example of historical volatility of the spot price for LNG and the resulting variability in our revenue.

To the extent we are unable to sell any such remaining LNG, our revenues will be adversely impacted, and any such impact could be significant. In addition, we will likely still be required to pay certain of our operating expenses

 

27


Table of Contents

related to the anticipated production of such remaining LNG (such as pipeline transportation costs) without generating any corresponding revenue. As a result, any such shortfall would also reduce our operating margins. Any of the foregoing could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

In addition, VG Commodities has contracted to resell at least 50% of the LNG generated by the Calcasieu Project in excess of its nameplate capacity (subject to an annual cap at the option of the counterparty). Pursuant to such agreement, the counterparty is entitled to an assignment of VG Commodities’ rights under the applicable Intercompany Excess Capacity SPA in certain cases (including but not limited to when an event of default by VG Commodities has occurred and not been cured pursuant to such agreement with the counterparty). In addition, we may enter into similar arrangements related to the excess LNG at our other projects in the future.

Our customers or we may terminate our SPAs if certain conditions are not met or for other reasons.

Each of our SPAs contains or will contain various termination rights allowing our current and future customers to terminate, or be relieved from their contractual obligations under, their SPAs under the circumstances described under “Business—Overview—Our Projects,” including, without limitation:

 

   

with respect to certain post-COD SPAs, the failure of certain conditions precedent to be satisfied or waived by a specified date, or delays in the occurrence of COD beyond a specified time period;

 

   

if we fail to make available specified scheduled cargo quantities;

 

   

upon the occurrence of certain extended events of force majeure;

 

   

if we have been held liable in excess of certain liability caps and we did not agree to increase such liability caps as specified under the relevant SPA;

 

   

our failure to satisfy our contractual obligations after an event of default and after any applicable cure periods; and

 

   

the occurrence of certain change of control events.

For example, we notified all of our customers under the Calcasieu Project post-COD SPAs of the anticipated delay to COD, indicating that such delay constitutes a force majeure event. As a result of such designation, the time period within which to achieve COD in such SPAs would be extended and such customers will not be entitled to terminate as a result of failure to designate COD until June 2025, at the earliest. All of such customers have questioned whether, and most have disputed in arbitration proceedings that, the delay constitutes a force majeure event, and they could assert that they are entitled to terminate their SPAs because COD did not occur by March 2024. See “—Risks Relating to Regulation and Litigation—We are involved and may in the future become involved in disputes and legal proceedings” and “—Risks Relating to Regulation and Litigation—If we are unsuccessful in our current and any potential future arbitration proceedings with our customers, the amounts that we are required to pay may be substantial and certain of our post-COD SPAs may be terminated, which may lead to an acceleration of all our debt for the relevant project.”

In addition, the CP2 Foundation SPAs include termination rights in favor of the customer and us if certain conditions precedent are not satisfied by us or waived by the customer by a certain date including that we receive all LNG export authorizations by that date. Because of the rehearing order issued by FERC on November 27, 2024 requiring a supplemental environmental review and the delay in issuance of authorizations to proceed with construction on the CP2 Project until FERC issues a further merits order and the temporary pause on new authorizations of natural gas exports to Non-FTA Nations described under “Business—Governmental Regulation—DOE Export Authorizations,” some of our customers under the CP2 Foundation SPAs or we may elect to terminate such SPAs if the related conditions precedent are not satisfied by the applicable deadline. Such dates certain have passed in two of the CP2 Foundation SPAs and are upcoming in March 2025 in the remaining CP2 Foundation SPAs. Although most customers have agreed to extend their original deadlines until March 2025, we are negotiating

 

28


Table of Contents

an extension with those CP2 Foundation SPA customers whose current deadlines have passed and not yet been extended. There can be no assurance that we will come to an agreement regarding an extension with such customers, and if we do not come to an agreement, either we or such customers may elect to terminate their respective SPA after the applicable grace period. Further, there can be no assurance that we will be able to secure any necessary extensions on similar terms with the CP2 Foundation SPA customers or at all if the future deadlines are not met in the event of further delays or otherwise.

While we could potentially replace any SPAs that are terminated by our customers or us, we may not be able to replace these SPAs on similar or favorable terms, or at all, if they are terminated. Further, under certain financing agreements, we may be required to maintain in effect (subject to our ability to replace them) certain long-term SPAs for a particular project, and any breach of such requirement may, unless certain prepayments are made, result in an event of default under such agreements, as well as a cross-default under our other financing agreements for that project or otherwise. As a result, a termination of certain SPAs could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Our ability to generate cash under our post-COD SPAs is substantially dependent upon the performance by a limited number of our customers, and we could be materially and adversely affected if certain of these customers fail to perform their contractual obligations for any reason.

We expect to have a limited number of customers to whom we sell LNG on a post-COD basis. For example, as of September 30, 2024, we have executed 39.25 mtpa of post-COD SPAs with 20 customers with respect to LNG from our projects as described under “Business—Overview—Our Projects.” 37.45 mtpa of such 39.25 mtpa is contracted under 20-year fixed price SPAs and 1.8 mtpa of such 39.25 mtpa is contracted on a short- and medium-term basis. For the nine months ended September 30, 2024, approximately 73% of our revenue for the period from individual external customers was concentrated across three customers. Moreover, for the nine months ended September 30, 2024, we had one customer which represented approximately 31% of our revenue for that same period.

The ability of our customers to perform their respective obligations to us will depend on numerous factors that are beyond our control. Our future results, our ability to service any debt we may incur and our liquidity are substantially dependent upon the performance of these customers under their contracts, and on such customers’ continued willingness and ability to perform their contractual obligations. We are also exposed to the credit risk of any guarantor of the customers’ obligations under their respective agreements if we must seek recourse under a guaranty. Any such credit support may not be sufficient to satisfy the obligations in the event of a counterparty default. In addition, if a controversy arises under an agreement resulting in a judgment in our favor where the counterparty has limited assets in the United States to satisfy such judgment, we may need to seek to enforce a final U.S. court judgment or arbitral award in a foreign tribunal, which could involve a more lengthy and less certain process and also result in additional costs.

Certain of our existing SPAs limit, and our future SPAs may limit, the liability of the relevant customer or its guarantor (or both). As a result, if a customer fails to perform its obligations under an LNG sales contract (including, for example, by failing to take or pay for the contracted volume of LNG), our ability to recover from that customer or from any guarantor of its obligations would be subject to any agreed upon limitations on liability. In addition, our existing SPAs excuse, and we expect that our future SPAs will excuse, performance by our customers upon the occurrence of force majeure events, such as certain severe adverse weather conditions, the breakdown or failure of its LNG tankers and acts of God.

Failures by certain of our customers to perform their obligations, or our inability to recover from such customers or the applicable guarantors, could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

 

29


Table of Contents

Our operating margins may be adversely affected if the price of natural gas decreases, if we pay a premium for feed gas relative to the contractual spot price we charge our customers, or as a result of inflationary pressures.

Our post-COD and other SPAs typically require, and we expect our future SPAs will require, our customers to pay a fee equal to a fixed facility charge per MMBtu, plus an amount equal to, depending on the applicable SPA, 115% or more of the Henry Hub price for feed gas that covers the cost of feed gas and is intended to cover gas transportation costs and certain of our other operating expenses. As a result, any decrease in the price of feed gas may reduce our operating margins under our SPAs.

In addition, there can be no assurance that the terms of our SPAs will pass through the actual price we pay for the supply and transport of feed gas to produce LNG under such SPAs. While we expect to manage our portfolio of gas supply to match the Henry Hub price we charge our customers under SPAs, there can be no assurance that we will be able to do so, particularly in times of volatility in the price of natural gas. If we are required to purchase feed gas at a premium relative to the Henry Hub price used to calculate the fee under the relevant LNG sales contract due to unexpected market factors or otherwise, our operating margins would be reduced.

We also anticipate that certain post-COD SPAs we enter into will include a fixed fee that will only be partially adjusted for inflation over the contract term. As a result, inflationary pressures over time will not be fully reflected in the prices we charge our customers under our post-COD SPAs. At the same time, our operating expenses are likely to increase due to inflationary pressure. Any such increases may not be fully offset by any partial inflation adjustments under our post-COD SPAs and, as a result, inflation may reduce our operating margins.

Any reduction in our operating margins as a result of these factors could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We may not be able to purchase or receive physical delivery of sufficient natural gas to satisfy our delivery obligations under the SPAs, which could have a material adverse effect on us.

We depend upon third-party pipelines to provide gas delivery options to our projects and any other natural gas liquefaction and export facilities that we may decide to develop in the future. We have entered into several precedent and service agreements with interstate pipeline companies to provide the natural gas transportation to the Calcasieu Project and the Plaquemines Project. We have begun to contract for natural gas transportation requirements for the CP2 Project and are currently in negotiations with other gas transportation companies to provide further natural gas transportation requirements for the CP2 Project and the natural gas transportation requirements for the CP3 Project and the Delta Project. We will need to enter into and secure additional pipeline transportation capacity for the CP2 Project, the CP3 Project and the Delta Project for us to generate the expected nameplate and excess capacity of LNG at such projects. There can be no assurance that we will be able to enter into the requisite agreements to secure natural gas transportation capacity on terms acceptable to us, or at all, which would impair our ability to fulfill our obligations under any SPAs. Even if we have entered into the requisite agreements for our projects, there can be no assurance we will be able to secure the necessary natural gas transportation capacity for each of our projects.

In addition, we depend on third-party natural gas suppliers to provide the feed gas required to generate the expected nameplate and excess capacity of LNG at our projects. We anticipate that we will establish and maintain a portfolio of natural gas supply agreements or contracts to meet our requirements, which we have commenced for the Calcasieu Project and the Plaquemines Project, but there can be no assurance that we will be successful in doing so on a long-term basis.

We also cannot control the regulatory and permitting approvals or third parties’ construction times, either with respect to capacity that has been secured or capacity that will be secured. If and when we need to replace

 

30


Table of Contents

one or more of our agreements with these interconnecting pipelines or enter into additional agreements, we may not be able to do so on commercially reasonable terms or at all, which would, in turn, impair our ability to fulfill our obligations under certain of our SPAs. Our failure to purchase or receive physical delivery of sufficient quantities of natural gas could prevent us from meeting our obligations under our SPAs and our ability to generate revenue would be adversely affected, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. In addition, if we are unable to deliver any contracted volume in full, our customers will generally be entitled to reimbursement of costs and expenses for replacement LNG.

Total contracted revenue is based on certain assumptions and is presented for illustrative purposes only and actual sales under our SPAs may differ materially from such illustrative operating results.

We have included in this prospectus certain calculations of total contracted revenue as an illustrative metric reflecting revenue that could be generated under our post-COD SPAs as of a particular date for the remaining term of all such post-COD SPAs. These calculations are based on certain assumptions as described in the definition of “total contracted revenue” included under “Certain Important Terms.” Those assumptions include, among others, the development, completion and commissioning of each of the relevant projects (including obtaining any required regulatory approvals), estimated contracted volume for each project’s existing post-COD SPAs, assumed rate of inflation, and an assumed Henry Hub gas price per MMBtu. Such assumptions are based upon our management’s assessment of market comparables and other indicative pricing in the market and will be affected by various factors, including actual inflation rates and Henry Hub gas prices during the term of the relevant SPAs, performance by our customers under the applicable SPAs, as well as by the various risks and uncertainties relating to development, construction, commissioning and operation of each of our projects (including obtaining any required regulatory approvals) as described in this “Risk Factors” section. For example, actual inflation rates and actual Henry Hub gas prices during the term of the relevant SPAs will likely differ from the assumed rate of inflation and assumed Henry Hub gas price used in such calculation, and any such differences could be material. As a result, actual revenue generated under those SPAs will likely differ from the total contracted revenue included in this prospectus, and any such differences could be material. Investors should not place undue reliance on our illustrative calculations of the total contracted revenue.

We may not be successful in pursuing bolt-on expansion opportunities at our current projects, which would adversely impact our growth prospects.

A key element of our growth strategy is to increase the liquefaction capacity at certain of our projects through bolt-on expansions that involve adding incremental liquefaction trains and certain related equipment to the relevant project. Our ability to pursue any such bolt-on expansion is subject to a number of risks and uncertainties and there can be no assurance that we will be able to complete all or some of our currently anticipated bolt-on expansion opportunities.

In particular, bolt-on expansion opportunities are subject to regulatory approval, and to date we have not made any filings with the necessary regulators, including DOE or FERC, with respect to any such expansion opportunities at our current projects. Such regulatory approvals are subject to numerous risks and uncertainties as described under “—Risks Relating to Regulation and Litigation,” and there can be no assurance that we will be successful in obtaining any such regulatory approvals. In addition, we aim to self-fund any bolt-on expansions using operating cash flows, and there can be no assurance our projects will generate sufficient cash proceeds to fund all of the expansion opportunities we have identified at our current projects. Further, any bolt-on expansion will require sufficient additional natural gas supply at the relevant project, and there can be no assurance we will be able to enter agreements for supply or transportation of the requisite natural gas on terms acceptable to us or at all.

Additionally, the development and construction of any bolt-on expansions at our current projects could have an adverse effect on the ongoing construction, commissioning or operations, as applicable, of the relevant

 

31


Table of Contents

projects. The simultaneous construction and subsequent commissioning of any bolt-on expansion opportunities at any project while such project is otherwise in construction, commissioning, or operating at full capacity, could subject us and our third-party contractors to additional safety risks, as well as additional costs related to the management of those safety hazards and additional required regulatory approvals. Any such additional safety or other measures and approvals could result in additional costs, could delay our plans for any such expansions, or could result in a smaller size of any potential bolt-on expansion opportunity.

If we are not successful in pursuing bolt-on expansion opportunities that we have identified at our projects, or if any such expansion opportunities are executed only at a smaller scale or on a delayed timeline, our growth would be adversely impacted. Any of the foregoing could have an adverse effect on our growth, financial condition, operating results, cash flow, prospects and the price of our Class A common stock.

Seasonal fluctuations will cause our business and results of operations to vary among quarters, which could adversely affect our business and results of operations, which could, in turn, negatively affect the price of our Class A common stock.

Our results of operations have fluctuated on a quarterly basis in the past, and may continue to fluctuate in the future, due to a wide variety of factors, including but not limited to the seasonal nature of demand for natural gas and LNG, third-party supply disruptions, price spread between European and Asian LNG indices, the availability of, and associated freight rates of, LNG tankers and temperature and weather conditions across the markets we supply, which can have an impact on the demand for energy and, consequently, LNG. Accordingly, fluctuations in revenue during quarters of high and low demand, respectively could have a disproportionate effect on our results of operations for the entire year. Thus comparisons of our results of operations across different fiscal quarters may not be accurate indicators of our future performance. Annual or quarterly comparisons of our results of operations may not be useful and our results in any particular period will not necessarily be indicative of the results to be expected for any future period. While we believe that our results of operations and earnings potential should be analyzed on a longer term view due to the nature of our business, such fluctuations can adversely affect our business and results of operations, which could negatively affect the price of our Class A common stock.

Our limited diversification could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Substantially all of our anticipated revenue will be dependent upon our LNG projects, all of which are currently located in southern Louisiana. Due to our limited asset and geographic diversification, an adverse development at the terminal or pipeline for our projects (including, for example, natural or man-made disasters affecting Louisiana, or significant long-term equipment failures), or in the LNG industry, would have a significantly greater impact on our financial condition and operating results than if we maintained more diverse assets and operating areas.

In the ordinary course of our business, we explore acquisitions and other targeted investments in areas of the natural gas industry that relate to our natural gas liquefaction and export projects that could negatively affect our operating results, increase our debt or cause us to incur significant expense.

An element of our strategy is to support our LNG growth through targeted transactions in areas of the natural gas industry that relate to our natural gas liquefaction and export projects. We intend to continue to explore targeted investments and acquisitions in the natural gas industry that complement and strengthen our project portfolio and solidify access to, and transport for, natural gas molecules, and the ability to deliver LNG, at commercially attractive terms. See “Business—Our Business and Growth Strategies.” For example, we have acquired firm regasification facility capacity at the largest LNG regasification terminal in Europe, Grain LNG, in the United Kingdom, which we expect will allow us to import 42 LNG cargos per year beginning, depending on

 

32


Table of Contents

the starting period, anytime between October 1, 2029 to April 1, 2030, to and until July 14, 2045 (except for the period from April 1, 2030 to September 30, 2030 when only 13 LNG cargos can be imported). Additionally, we have secured approximately 1 mtpa of LNG regasification capacity at the new Alexandroupolis LNG receiving terminal in Greece for five years, beginning in 2025. Our capacity will account for approximately 25% of the total terminal capacity at Alexandroupolis, or approximately 12 cargos annually. While we believe that these contracted regasification capacities will allow us to supply both LNG and regasified natural gas directly into the European market to current and future downstream customers and allow us to continue to grow our presence in the European markets, we cannot guarantee that demand for delivered LNG or regasified natural gas will be in line with our expectations to secure additional regasification capacity in key import markets. See “—Risks Relating to Our Projects and Other Assets—Management and operation of our LNG tanker fleet and the subcharter of third-party vessels will involve significant risks.”

We have limited experience with pursuing such expansions of our business through acquisitions or investments, which may be in areas to our business that relate to our natural gas liquefaction and export projects. Such acquisitions or investments may expose us to new risks not presently faced by our business. If we make any acquisitions, we may not be able to integrate these acquisitions successfully into our existing business, and we could assume unknown or contingent liabilities. In addition, we may enter into agreements with counterparties outside the U.S., which would expose us to political, governmental, and economic instability, foreign currency exchange rate fluctuations and corruption risk, all of which could be exacerbated by our lack of experience doing business in such other markets. Any future acquisitions also could result in the incurrence of debt, potential violations of covenants in our debt instruments, contingent liabilities, insufficient revenue acquired to offset liabilities assumed, unexpected expenses, inadequate return of capital, regulatory or compliance issues, potential infringements, difficulties integrating such acquired companies into our operations, and other unidentified issues not discovered in due diligence or future write-offs of intangible assets or goodwill, any of which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. Integration of an acquired company also may disrupt ongoing operations and require management resources that we would otherwise focus on developing our existing business and projects. We may experience losses related to investments in other companies, and we may not realize the anticipated benefits of any acquisition, strategic alliance or joint venture. Accordingly, if such initiatives are not successful, this could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Severe weather events, hurricanes, or other disasters could result in an interruption of our operations, a delay in the completion of our projects, higher construction costs and the deferral of the dates on which we would become entitled to receive payments under any SPAs, all of which could adversely affect us.

Severe weather, including hurricanes and winter storms, can be destructive, causing construction delays, outages and property damage that require incurring additional expenses. Furthermore, our operations could be adversely affected, and our physical facilities could be at risk of damage, should changes in global climate produce, among other conditions, unusual variations in temperature and weather patterns, resulting in more intense, frequent and severe weather events, abnormal levels of precipitation or a change in sea level or sea temperatures. Although the current design of each of our projects includes perimeter walls to protect against storm surge, there can be no assurance that they will be effective to protect against any of these events. In particular, all of our LNG projects that are currently under construction or development are in Southern Louisiana, which has historically been exposed to severe weather events and hurricanes. For example, in August and October 2020, respectively, Hurricanes Laura and Delta struck the Louisiana coast, with Hurricane Laura passing directly over the Calcasieu Project site.

Future storms and related storm activity and collateral effects, or other disasters such as explosions, fires, floods or accidents, could result in damage to, or interruption of operations at, our projects or related infrastructure, as well as delays or cost increases in the construction and the development of our projects and following the completion of our projects, interruption of operations of our projects. Changes in the global climate

 

33


Table of Contents

may have significant physical effects, such as increased frequency and severity of storms, floods, and rising sea levels. If any such effects were to occur, they could have a material adverse effect on our coastal operations.

We will be unable to insure against all potential risks and may become subject to higher than expected insurance premiums. In addition, we retain certain risks as a result of insurance through our captive insurance.

Although we have obtained insurance coverage in respect of the Calcasieu Project, the Plaquemines Project, and with respect to third-party liability coverage, the CP2 Project, and standard hull and machinery insurance and protection and indemnity insurance for our LNG tankers, we do not currently maintain insurance with respect to most aspects of the development, construction or operation of our other projects. We expect to obtain insurance consistent with industry standards (subject to availability on commercially reasonable terms) to protect against certain construction, operating and other risks, but not all risks will be insured or are insurable (for example, losses as a result of force majeure, natural or man-made disasters, terrorist attacks or sabotage or environmental contamination may not be available at all or on commercially reasonable terms). However, there can be no assurance that such insurance coverage will be available in the future on commercially reasonable terms or at commercially reasonable rates, or on the same or substantially similar terms as our existing insurance coverage or that the insurance proceeds will be adequate to cover the repair or replacement of equipment and materials, to cover lost revenues from our projects, or to compensate for any injuries or loss of life. If certain operating risks occur, or if there is a total or partial loss of a project in the future, there can be no assurance that the proceeds of the applicable insurance policies will be adequate to cover lost revenues, increased expenses or the cost of repair or replacement. Additionally, in the event we make a claim under our insurance policies, we will be subject to the credit risk of the insurers. Volatility and disruption in the financial and credit markets may adversely affect the credit quality of our insurers and impact their ability to pay claims. Any increases in the number or severity of claims or any such loss that is not covered by our insurance policies could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We anticipate that insurance premiums for LNG projects may increase due to a continuing increase in demand by LNG projects seeking insurance coverage, and losses and claims that have arisen or been experienced in respect of other unrelated projects in other regions or losses and claims that are large enough to impact the broader insurance market. Furthermore, we anticipate insurance premiums for projects located in Louisiana may increase significantly following Hurricane Laura in August 2020, Hurricane Delta in October 2020, Hurricane Ida in August 2021, and Hurricane Ian in September 2022. Changes in global climate may produce, among other possible conditions, unusual variations in temperature and weather patterns, resulting in more intense, frequent and severe weather events, abnormal levels of precipitation or a change in sea level or sea temperatures. Future storms and related storm activity and collateral effects, or other disasters such as explosions, fires, floods or accidents, could result in further increases in insurance premiums. Any such increases in premiums could be significant and could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Furthermore, the Calcasieu Project and the Plaquemines Project each maintain a Named Windstorm Insurance Program, which is structured as a layered program with a limit of $250 million at each location, with VGLNG Insurance, LLC, or VGLNG Insurance, one of our subsidiaries. See “Business—Insurance—Named Windstorm Insurance (NWS).”

The use of captive insurance entities necessarily involves retaining certain risks that might otherwise be covered by traditional insurance products.

A major health and safety incident relating to our business could be costly in terms of potential liabilities and reputational damage.

Health and safety performance is critical to the success of all areas of our business. Any failure in health and safety performance may result in personal harm or injury, damage to property, fines or penalties for

 

34


Table of Contents

non-compliance with relevant regulatory requirements or litigation, and a failure that results in a significant health and safety incident is likely to be costly in terms of potential liabilities. Such a failure could generate public concern and have a corresponding impact on our reputation and our relationships with relevant regulatory agencies and local communities, which in turn could have a material adverse effect on the price of our Class A common stock.

Failure to retain and attract executive officers and other skilled professional and technical employees or increased labor costs could have a material adverse effect on our operations.

Our business strategy is dependent on our ability to recruit, retain and motivate employees. Competition for skilled management employees for our various business and administrative operations is high. In addition, demand for skilled professional, technical and operations employees is high in the fields of engineering, construction, operations and gas transportation. Demand for these employees is high due to growth in demand for natural gas, increased supply of natural gas as a result of developments in gas production, increased infrastructure projects, and increased regulation of these activities. There can be no assurance that we will successfully recruit or retain qualified personnel, and our inability to retain and attract these employees could adversely affect our business and future operating results.

Furthermore, while most of our executive officers are required to devote substantially all of their time to our business, if other business interests of our executive co-chairmen require them to devote substantial amounts of time, it could limit their ability to devote time to our business which may have a negative impact on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Our operating results depend in significant part upon the continued contributions of key senior management and technical personnel. Continued successful operation of our projects and management of growth if we expand requires, among other things:

 

   

continued development of financial and management systems;

 

   

implementation of adequate internal control over financial reporting and disclosure controls and procedures;

 

   

hiring and training of new personnel; and

 

   

coordination among logistical, technical, accounting, finance, information technology, administrative, and commercial personnel.

An inability to manage successfully any of these factors could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, liquidity, financing requirements, prospects, and the price of our Class A common stock.

We are dependent on the strategic direction of Michael Sabel, our Chief Executive Officer, Executive Co-Chairman of the Board and Founder, and Robert Pender, our Executive Co-Chairman, Executive Co-Chairman of the Board and Founder.

Mr. Sabel and Mr. Pender are, through VG Partners, our controlling shareholders, and therefore have significant influence on, and are drivers of, our business planning, strategy, and culture. Our success depends to a significant degree on their leadership, long-term vision, relationships, knowledge of the industry, and ability to execute our overall business strategy. If either Mr. Sabel or Mr. Pender were to discontinue their service with us due to death, disability or any other reason, it could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

 

35


Table of Contents

We and our contractors, including our EPC contractors, may experience increased labor costs, and the unavailability of skilled workers or our failure to attract and retain qualified personnel could adversely affect us.

Before construction of any project begins, we and our contractors, including our EPC contractors, need to hire new on-site employees to manage the construction of each project. We have engaged an EPC contractor to meet some of the construction labor needs of the Plaquemines Project and Phase 1 of the CP2 Project and we plan to engage EPC contractors to meet some of the construction labor needs of Phase 2 of the CP2 Project, the CP3 Project, the Delta Project, and any future projects we develop. In addition, before any of our projects commences operations, we need to hire an entire staff to operate the applicable facility. As a result, we expect the number of our personnel and our related costs to continue increasing significantly as we grow. If we and our contractors, including EPC contractors, are not able to attract and retain qualified personnel, this could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Construction, operation and maintenance of our facilities requires highly skilled personnel. There may be a limited supply of such personnel as a result of many factors, including intense competition to attract and retain the services of such persons. This competition may increase as additional LNG projects and other large-scale infrastructure projects are developed and constructed in North America, and in particular, the Gulf Coast of the United States. As a result, we and our contractors, including EPC contractors, may face shortages of qualified labor to construct, manage and operate our facilities, higher than anticipated labor costs or an inability to monitor, motivate and retain qualified personnel. An inability to recruit and retain such individuals could decrease productivity in the construction of our projects and in our operations. Competition for skilled employees could require us and our contractors, including EPC contractors, to pay higher wages, which could also result in higher labor costs.

Moreover, a shortage in the labor pool of skilled workers and other general inflationary pressures, which we and our contractors, including EPC contractors, have been experiencing recently and may experience in the future or changes in applicable laws and regulations could make it more difficult to attract and retain qualified personnel and could require an increase in the wage and benefits packages that are offered, thereby increasing our operating costs. Any increase in our operating costs could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We use and are planning to utilize various tax incentive programs the State of Louisiana offers that may not continue to be available or may be available in diminished form.

The State of Louisiana has various programs in place to incentivize investment in the state. These include sales tax rebates or exemptions, payroll tax credits, investment tax credits, inventory tax credits, and property tax exemptions. We have utilized such tax incentives where available for our existing projects and are planning to seek these tax benefits as well as any other tax benefits available to our other projects. However, owing to the fiscal difficulties the state has faced in recent years, some of these programs have come under scrutiny and, as a result, the benefits provided by those programs have been reduced. In addition, applicants for these benefits have been subjected to greater scrutiny by the state, and have been subjected to a greater burden in demonstrating that they meet the criteria (such as job creation requirements) for the award of such benefits. Furthermore, the grant of certain of these benefits may be challenged in court.

If such lawsuits were to prevail or we are otherwise unable to secure the benefit of any of these incentive programs, or if there are further reductions to the benefits provided by these incentive programs, the financial performance and results of operations and our plans for our projects may be adversely impacted.

 

36


Table of Contents

Our ability to use our net operating losses to offset future taxable income may be subject to certain limitations.

As of December 31, 2023, we have accumulated federal net operating loss, or NOL, carryforwards of $367 million with an indefinite carryforward period. We additionally had accumulated state net operating loss carryforwards of approximately $1.7 billion (after the application of state apportionment factors), of which $42 million will expire by 2037. Under the current tax law, federal NOLs incurred in taxable years beginning after December 31, 2017, can be carried forward indefinitely, but the deductibility of such federal NOLs in taxable years beginning after December 31, 2020 is limited to 80% of taxable income. These federal and state NOLs may be available to offset income tax liabilities in the future. In addition, we may generate additional NOLs in future years. NOLs may be limited by separate return limitation year, or SRLY, rules. These rules generally limit the use of NOL carryforwards to the amount of taxable income that the NOL producing entity contributes to consolidated taxable income during the year. Of the federal NOL carryforward amount stated earlier, $42 million is currently subject to the SRLY rules. NOLs subject to the SRLY limitations may also be subject to Section 382 limitations described below.

In general, under Section 382 of the Code, or Section 382, a corporation that undergoes an “ownership change” is subject to limitations on its ability to utilize its pre-change NOLs to offset future taxable income. For this purpose, an ownership change generally means a more than 50 percentage point change in the ownership of a corporation by one or more shareholders or specified groups of shareholders, each of which owns 5% or more of the corporation (determined after the application of certain attribution and grouping rules) over a three-year period. Although we do not believe that any of our NOLs are currently subject to limitation under Section 382, future changes in our stock ownership, including as a result of this offering or future changes, and some of which may be outside of our control, could result in an ownership change under Section 382, which could limit our ability to use our existing or future NOLs to offset future taxable income.

Risks Relating to Our Projects and Other Assets

We will require significant additional capital to construct and complete certain of our projects, and we may not be able to secure such financing on time with acceptable terms, or at all, which could cause delays in our construction, lead to inadequate liquidity and increase overall costs.

We are in the process of commissioning the Calcasieu Project, constructing the Plaquemines Project and developing the CP2 Project, the CP3 Project and the Delta Project. An amount expected to be necessary to complete the Calcasieu Project and achieve COD for the Calcasieu Project is held in cash reserve accounts pursuant to our project financing arrangements and reflected as restricted in our financial statements. While we believe we have sufficient project-level cash, borrowing capacity under our existing project-level debt financing, and access to substantial commissioning cargo proceeds to fund the completion of the Plaquemines Project based on our current estimate of the total project costs, the CP2 Project, the CP3 Project and the Delta Project, as well as any future projects we develop, will require significant additional funding.

We currently estimate that the total project costs for the Plaquemines Project will be approximately $22 billion to $23 billion, including EPC contractor profit and contingency, owners’ costs and financing costs, of which approximately $17.7 billion had been paid for as of September 30, 2024. As of September 30, 2024, we have additional available borrowing capacity of $2.6 billion under the Plaquemines Construction Term Loan. In addition, as of September 30, 2024, we estimate that the total project cost for the CP2 Project, the CP3 Project and the Delta Project will range from approximately $27 billion to $28 billion, $44 billion to $45 billion and $37 billion to $38 billion, respectively, in each case including EPC contractor profit and contingency, owners’ costs and financing costs, substantially all of which have not yet been funded. These estimates are based primarily upon our construction cost experiences with the Calcasieu Project and the Plaquemines Project and the pricing included in the CP2 Phase 1 EPC Contract, and reflect the current inflationary environment as well as the fact that the pipelines for the CP2 Project, the CP3 Project and the Delta Project are expected to be longer and more expensive than the

 

37


Table of Contents

pipelines for the Calcasieu Project and the Plaquemines Project. The CP3 Project and the Delta Project are also expected to be larger in scale than our first three projects, with expected nameplate capacity of 30.0 mtpa and 24.4 mtpa, respectively.

Moreover, no substantial construction work has been undertaken on either the CP3 Project or the Delta Project to date, we have not yet entered into a number of material contracts (including an EPC contract for Phase 2 of the CP2 Project, or any portion of the CP3 Project or the Delta Project) for the CP2 Project, the CP3 Project or the Delta Project, and our actual costs could vary significantly from our preliminary estimates depending on the terms we may agree to for those contracts. There is no guarantee that we will be able to enter into the necessary contracts to construct the CP2 Project, the CP3 Project, the Delta Project, or any other natural gas liquefaction and export facility we may decide to develop in the future, on the same or substantially similar terms as the Calcasieu EPC Contract, the Plaquemines EPC Contracts or the CP2 Phase 1 EPC Contract. As a result, our cost estimates are only an approximation of the actual costs of construction and financing for the CP2 Project, the CP3 Project and the Delta Project. Our actual project costs may be higher, potentially materially, compared to our current estimates as a result of many factors as described under “—Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.” For example, our cost estimates might change due to factors such as unexpected delays in the construction or commissioning of our projects, the execution of any repair or warranty work and change orders or amendments to certain material construction contracts, including final terms of or amendments to any EPC contract for such projects, and/or other construction or supply contracts. Accordingly, we will need to obtain significant additional funding from one or more sources of debt and equity financing before we are able to generate sales and/or revenue for our projects, other than the Calcasieu Project, and, based upon current estimates, the Plaquemines Project.

The amount of project-level equity funding that is required for any of our projects relative to the amount of project-level debt financing may differ between our projects. Generally, we expect to finance approximately 50% to 75% of the anticipated project costs of each of our projects with project-level debt financing (which may include limited recourse debt), and the remaining 25% to 50% with project-level equity (which may consist of equity contributions by us, equity financing transactions, mezzanine financing and/or other similar financing alternatives). However, the proportion of project-level debt to equity funding will depend on various factors, including market conditions and the amount of long-term contracted revenues for the relevant project. As a result, there can be no assurance as to the ultimate amount of project-level debt financing that will be available to us for a particular project on acceptable terms, which could have an adverse impact on our ability to finance the relevant project and may require us to raise additional debt, equity or equity-linked financing above relevant project entities, including potentially at the Company level, through additional debt, equity or equity-linked financing. We do not currently have any committed project-level debt or equity financing for the CP2 Project, the CP3 Project or the Delta Project. We may consider alternative structures to raise capital for those projects and, as a result, there can be no assurance that the financing structure for the CP2 Project, the CP3 Project, the Delta Project or any future project we may develop will be similar to those used for the Calcasieu Project and Plaquemines Project.

Additional capital may not be available in the amounts required, on favorable terms, or at all, and is subject to the risks described under “—Risks Relating to Our Indebtedness and Financing—Certain of our debt agreements impose significant operating and financial restrictions on our subsidiaries, and the preferred equity of our subsidiaries also gives the holders certain consent rights, all of which may prevent us from capitalizing on business opportunities or paying dividends to the Company.” In addition, if any adverse findings are discovered at any stage during the course of our development of our projects that would render part of, or all of, any such sites to be unsuitable or we discover flaws that may decrease the value of such sites as collateral for purposes of any financing, then we may not be able to obtain the financing necessary to construct the relevant project on favorable terms, or at all. For example, such adverse findings may include the discovery of environmental conditions on the relevant project site that require investigation, remediation or other changes to the relevant project or that make it more difficult for us to obtain the necessary regulatory approvals.

 

38


Table of Contents

Furthermore, any adverse changes in natural gas demand that affect the competitiveness of LNG or any failure on our part to obtain or comply with necessary permits or approvals may also hinder our ability to obtain necessary additional capital or financing. See “—Risks Relating to the LNG Industry—Cyclical or other changes in the demand for and price of LNG and natural gas may adversely affect our business and the performance of our customers and could have a material adverse effect on our business, contracts, financial condition, operating results, cash flows, liquidity and prospects and the price of our Class A common stock” and “—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

Delays in the construction of our projects beyond the estimated development period, issues with the commissioning process leading to additional repair and replacement work, as well as change orders to certain material construction contracts and/or other construction or supply contracts, could increase the cost of completion beyond the amounts that we estimate and beyond the then-available proceeds from sales of commissioning cargos we expect to receive, which could require us to obtain additional sources of financing to fund our operations until our projects are fully completed (which could cause further delays). For example, we have experienced unexpected delays in commissioning the Calcasieu Project related to certain necessary repairs and replacements. As a result, we expect COD for the Calcasieu Project to be delayed while significant work related to commissioning, carryover completions, rectification, and certain other items is being completed, and we are currently targeting a COD for the Calcasieu Project at the end of March 2025. Further, while we are generating commissioning cargo proceeds at the Calcasieu Project and plan to also sell commissioning cargos at each of our other projects, it is possible those commissioning cargo proceeds will be lower, potentially materially, than we currently anticipate, which could also require us to obtain additional sources of capital to fund development, construction and commissioning of our projects. See “—Risks Relating to Our Business—Our ability to generate proceeds from sales of commissioning cargos is subject to significant uncertainty and volatility in such proceeds. Historical proceeds from such sales at the Calcasieu Project, which has had an extended commissioning period due to unanticipated challenges with equipment reliability that we are in the process of remediating, may not be indicative of the duration of the commissioning period or the amount of proceeds for any future period or for any of our other projects.”

Our future liquidity may also be affected by the timing and availability of financing in relation to the incurrence of construction costs for our projects and other outflows and by the timing of receipt of cash flow under the SPAs in relation to the incurrence of various project and operating expenses. Moreover, many factors (including factors beyond our control) could result in a disparity between liquidity sources and cash needs, including factors such as construction delays and breaches of agreements.

Our ability to obtain financing that may be needed to provide additional funding will depend, in part, on factors beyond our control and there can be no assurances that funding will be available to us on commercial terms or at all. For example, capital providers or their applicable regulators may elect to cease funding LNG projects or certain related businesses. Accordingly, we may not be able to obtain financing on terms that are acceptable to us, or at all. Even if we are able to obtain financing, we may have to accept terms that are disadvantageous to us or that may have an adverse impact on our business plan and the viability of the relevant project. The failure to obtain any necessary additional funding could cause any or all of our projects to be delayed or not be completed. Any delays in construction could prevent us from commencing operations when we anticipate and could prevent us from realizing anticipated cash flows, all of which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We may not construct or operate all of our proposed LNG facilities or pipelines or any additional LNG facilities or pipelines beyond those currently planned, and we may not pursue some or any of the bolt-on expansion opportunities we have identified at our current projects, which could limit our growth prospects.

We may not construct some of our proposed LNG facilities or pipelines, and we may not pursue some or any of the bolt-on expansion opportunities we have identified at our current projects, in each case whether due to

 

39


Table of Contents

lack of commercial interest, inability to obtain financing, inability to obtain adequate supply of materials and equipment to complete construction of our projects, inability to obtain necessary regulatory approvals (including as a result of political factors, environmental concerns or public opposition) or otherwise. Our ability to develop additional liquefaction facilities or to pursue bolt-on expansion opportunities at our projects will also depend on the availability and pricing of LNG and natural gas in North America and other places around the world. If we are unable or unwilling to construct and operate additional LNG facilities or bolt-on expansion opportunities at our current projects, our prospects for growth will be limited.

When completed, our natural gas liquefaction and export projects, including the Calcasieu Project, the Plaquemines Project, the CP2 Project, the CP3 Project, the Delta Project, and any future projects we develop, may face significant operational risks.

As more fully discussed in these “Risk Factors,” the Calcasieu Project, the Plaquemines Project, the CP2 Project, the CP3 Project and the Delta Project and any other natural gas liquefaction and export facilities that we may decide to develop in the future involve operational risks, including the following:

 

   

explosions, pollution, releases of toxic substances;

 

   

the facilities performing below expected levels of efficiency;

 

   

breakdown or failures of equipment;

 

   

unanticipated changes in domestic and international market demand for and supply of natural gas and LNG, which will depend in part on supplies of and prices for alternative energy sources and the discovery of new sources of natural resources;

 

   

operational errors by vessel or tug operators;

 

   

operational errors by us or any contracted facility operator;

 

   

labor disputes; and

 

   

weather-related interruptions of operations, natural disasters, fires, floods, accidents or other catastrophes.

If any of such operational risks materializes, it could have a material adverse effect on our current or future business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We have multiple procurement and construction contracts. Failure by one contractor to perform under its applicable material procurement and/or construction contract could lead to failure to perform or delay in performance by others under their construction contracts.

Our strategy for each project involves us entering into and administering a number of procurement and construction contracts, which differs from certain other LNG projects of this scale developed in the United States.

Failure of any of the counterparties to these procurement and/or construction contracts to complete its contractual obligations on a timely basis could result in material delays in the ability of our projects to achieve commercial operation. In addition, any such failure by any of the foregoing counterparties could affect the schedule of other construction contractors and/or require change orders to multiple material construction contracts. Although the scope of each such contractor is defined in the applicable material contract to which it is a party, in the event of delays or other procurement or construction issues, each such contractor may seek to shift responsibility for delays or other issues to other contractors, resulting in increased costs or delays.

 

40


Table of Contents

We are dependent on our contractors for the successful completion of our projects and any bolt-on expansion opportunities at our projects that we may pursue, and any failure by our contractors to perform their contractual obligations could have a material adverse impact on our projects.

There is limited recent industry experience in the United States regarding the construction or operation of mid-scale natural gas liquefaction and export facilities. Timely and cost-effective completion of our projects or any bolt-on expansion opportunities at our projects in compliance with agreed-upon specifications is highly dependent upon the performance of our contractors pursuant to their agreements with us. Moreover, our construction strategy involves multiple construction contracts, which differs from certain other LNG projects of this scale developed in the United States. Failure by one contractor to perform under its applicable material construction contract could lead to failure to perform or delay in performance by others under their construction contracts.

Successful construction and operation of our projects, or any bolt-on expansions at our projects, will depend on the adequacy and timeliness of performance of our contractors. The failure of our contractors to perform as expected could have a material adverse impact on our ability to complete our projects, or any bolt-on expansions at our projects, on our anticipated schedule and budget, or at all. Further, if the completion and the commercial operation dates of the Calcasieu Project or the Plaquemines Project are delayed beyond an agreed date certain for each project, an event of default under the Calcasieu Pass Credit Facilities, the VGCP Senior Secured Notes and the Plaquemines Credit Facilities may occur. See “—Risks Relating to Our Indebtedness and Financing— Upon the occurrence of an event of default under our existing and future indebtedness, our lenders and the holders of our debt securities could elect to accelerate all or a portion of our debt. A delay in COD of the Calcasieu Project or Phase 1 or 2 of the Plaquemines Project beyond a certain deadline could also result in an event of default under the Calcasieu Pass Credit Facilities or the Plaquemines Credit Facilities, respectively, and/or certain investors exercising step-in rights to control, directly or indirectly, certain of our subsidiaries and the Calcasieu Project” and “—Delays in the construction of our projects beyond the estimated development periods could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.”

Further, our ability to complete our projects, or any bolt-on expansions at our projects, and commence operations at each of our projects, or any bolt-on expansions at our projects, depends on completion of construction of our projects, or any bolt-on expansions at our projects, in accordance with our design and quality standards. Faulty construction that does not conform to those standards could have a material impact on our ability to complete our projects, or any bolt-on expansions at our projects, on our anticipated schedule, and could also have material adverse effects on the operation of the facilities (for example, improper equipment installation may lead to a shortened life of our equipment, increased operations and maintenance costs or a reduced availability or production capacity of the affected facility).

Timely and cost-effective completion of the projects, or any bolt-on expansions at our projects, in compliance with agreed specifications is central to our business strategy and is highly dependent on the performance by the construction contractors of their obligations under the material construction contracts. The ability of our current or intended contractors to complete our projects in accordance with our design and quality standards and on our anticipated schedule is dependent on a number of factors, including such construction contractor’s ability to, as applicable:

 

   

maintain its own financial condition, including adequate working capital, and its ability to pay debt service and other liabilities;

 

   

accurately estimate certain costs, including material, construction and fabrication costs, from third parties such as suppliers and subcontractors;

 

   

respond to difficulties such as equipment failure, increased costs, delivery delays, schedule changes and failure to perform by subcontractors, some of which are beyond their control;

 

41


Table of Contents
   

design, engineer and build the facilities constituting the projects to operate in accordance with specifications and on schedule;

 

   

engage and retain third-party subcontractors and procure equipment and supplies;

 

   

attract, develop and retain skilled personnel, including engineers, and address any labor issues that may arise;

 

   

respond to market conditions in the construction industry, including recent shortages of personnel and recent increases in operating costs;

 

   

address any start-up and operational issues that may arise in connection with the commencement of commercial operations;

 

   

post and maintain required construction bonds or other performance assurance and comply with the terms thereof; and

 

   

manage the construction process generally, including coordinating with other contractors, third-party contractors and regulatory agencies.

Although agreements with our contractors may provide for liquidated damages if the relevant contractor fails to perform its obligations under the applicable agreement, such failure may delay or permanently impair the operations of our projects, or any bolt-on expansions at our projects. Moreover, any liquidated damages that we may be entitled to receive may be subject to certain liability caps, and may not be sufficient to cover the damages that we suffer, or that we may be required to pay to our customers or our lenders as a result of any such delay or impairment. Furthermore, we may have disagreements with our current or intended contractors about different elements of the construction process or our construction contracts, which could lead to the assertion of rights and remedies under the related contracts resulting in increases to the cost of the project, or any bolt-on expansions at our projects, or such contractor’s unwillingness to perform further work on our projects, or any bolt-on expansions at our projects, or to pay liquidated damages. For example, we had disagreements regarding certain disputed costs and bonuses with Kiewit, our EPC contractor for the Calcasieu Project that were submitted to arbitration. Such disputes were fully resolved in 2024 and resulted in the payment of approximately $320 million, in the aggregate, to Kiewit.

In addition, if our current or intended contractors, or any of their parents or affiliates that provide performance guarantees, letters of credit or similar credit support, consummate any significant acquisitions, dispositions, restructurings or other strategic transactions, or become subject to bankruptcy or similar proceedings, our ability to complete our projects, or any bolt-on expansions at our projects, in accordance with our design and quality standards and on our anticipated schedule, and our ability to recover under any such performance guarantees, letters of credit or similar credit support, may be adversely affected.

For example, the Plaquemines Project is being constructed pursuant to two integrated EPC contracts, one per phase, or the Plaquemines EPC Contracts, that we entered into with KZJV, LLC, or KZJV, a limited liability company that is owned by Kellogg Brown & Root LLC, or KBR EPC Member, and Zachry Industrial, Inc., or Zachry Industrial. In May 2024, Zachry Industrial, along with Zachry Holdings, Inc., or Zachry Holdings, one of the parent guarantors under the Plaquemines EPC Contracts for the Plaquemines Project, and certain of their affiliates filed for bankruptcy protection under Chapter 11 of the U.S. bankruptcy code, or the Zachry Bankruptcy. Although it is our understanding that KZJV, Zachry Industrial, and KBR EPC Member are committed to avoiding any disruption to the Plaquemines Project, there can be no assurance that the Zachry Bankruptcy will not have a material adverse impact on the project. In particular, the bankruptcy court could authorize Zachry Industrial and/or Zachry Holdings to take various actions that could adversely impact KZJV, the Plaquemines Project, the Plaquemines EPC Contracts and the related performance security and parent guarantees, including rejecting or otherwise impairing Zachry Holdings’ parent guarantee, seeking to sell or otherwise monetize Zachry Industrial’s interest in KZJV, or otherwise rejecting any contractual obligations of Zachry Holdings and its affiliates in connection with the Plaquemines EPC Contracts. In addition, the Zachry

 

42


Table of Contents

Bankruptcy may result in the exercise of any applicable termination or step-in rights in connection with the KZJV limited liability company agreement and any related arrangements as well as disputes between KBR EPC Member and Zachry Industrial, or their parent guarantors, with respect to the KZJV joint venture and their respective obligations in connection with the Plaquemines EPC Contracts, which may adversely impact KZJV’s, its members’ or its parent guarantors’ willingness or ability to perform their respective contractual obligations in connection with the Plaquemines EPC Contracts and related parent guarantees. Such events may also constitute an event of default under the Plaquemines EPC Contracts. If KZJV is unable or unwilling to perform according to the negotiated terms and timetable of the Plaquemines EPC Contracts, we may decide to engage a substitute EPC contractor, which could result in material cost increases and/or delays in the ability of both phases of the Plaquemines Project to achieve commercial operations. There also can be no assurance that we would be able to enter into an EPC contract with any such substitute EPC contractor on similar terms, or at all. Further, the Zachry Bankruptcy resulted in an event of default under the related project financing for the Plaquemines Project. While the relevant lenders waived such event of default, there can be no assurance they would waive any further events of default that occur in the future, and the occurrence of any such further event of default, if not waived, would allow the lenders to accelerate such project financing and foreclose on the collateral securing such financing. Any of the foregoing could result in material delays or termination of the Plaquemines Project, and could have a material adverse impact on our ability to complete the Plaquemines Project on our anticipated schedule and budget, or at all. In addition, if we are not able to recover under the Zachry Holdings parent guarantee, we may not be able to recover in full any damages or other amounts we are entitled to under the Plaquemines EPC Contracts even though the KBR, Inc. and Zachry Holdings parent guarantees provide for joint and several liability.

If any contractor or supplier is unable or unwilling to perform according to the negotiated terms and timetable of its respective agreement for any reason or terminates its agreement, we would be required to engage a substitute contractor or supplier. This would likely result in significant project delays and increased costs, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We have not entered into all of the definitive agreements for the CP2 Project, the CP3 Project or the Delta Project, and there can be no assurance that we will be able to do so on a timely basis or on terms that are acceptable to us.

To date, we have not yet entered into all of the necessary definitive agreements with the key suppliers and contractors necessary for development and construction of the CP2 Project, other than purchase orders with Baker Hughes Energy Services LLC, or Baker Hughes, for liquefaction systems and power island systems for both phases of the CP2 Project, the CP2 Phase 1 EPC Contract, an EPC contract for the LNG storage tanks with CB&I for Phase 1 of the CP2 Project, certain natural gas pre-treatment system licensing, engineering and procurement agreements, and an agreement for the construction of the perimeter wall of the CP2 Project. Additionally, we have entered into the Baker Hughes Master Agreement, which provides for the potential supply of liquefaction systems and power island systems that could be utilized, as applicable, for the CP3 Project, the Delta Project, and certain other projects we may develop in the future. Further, we have not entered into any of the necessary definitive agreements with the key suppliers and contractors necessary for the development and construction of the CP3 Project and the Delta Project other than the Baker Hughes Master Agreement. We may not be able to successfully negotiate the outstanding necessary definitive contracts for the CP2 Project, the CP3 Project or the Delta Project, or other projects we may develop in the future, on terms or at prices that are acceptable to us. Our inability to negotiate and execute definitive agreements with such contractors on terms acceptable to us could have a material adverse impact on our ability to complete the CP2 Project, the CP3 Project or the Delta Project, and any projects we may develop in the future, on our anticipated schedule and budget, or at all.

In particular, we have not yet entered into an EPC contract for Phase 2 of the CP2 Project, the CP3 Project or the Delta Project, and there can be no assurance that we will be able to do so on a timely basis or at all. If we

 

43


Table of Contents

are unable to negotiate an EPC contract for Phase 2 of the CP2 Project, the CP3 Project or the Delta Project on a timely basis and on terms that are acceptable to us or that are similar to the terms in the Calcasieu EPC Contract, the Plaquemines EPC Contracts and the CP2 Phase 1 EPC Contract, the development and construction of Phase 2 of the CP2 Project, the CP3 Project or the Delta Project may be delayed or they may not be built at all, and the construction cost of the CP2 Project, the CP3 Project or the Delta Project may be greater than our current estimates.

Any of the foregoing could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Certain of our contractual arrangements relating to development and construction of our projects include termination rights that, if exercised, could have a material adverse impact on our projects.

Certain of our contractual arrangements relating to the development and construction of one or more of our projects include termination rights or changes to the applicable pricing, or will automatically expire, if certain conditions are not met by specified deadlines.

For example, under the Baker Hughes Master Agreement, if we fail to enter into purchase orders for the liquefaction systems and the power plant for our future development projects by certain mutually agreed dates or to begin making scheduled payments, then Baker Hughes’ obligations to supply such equipment will expire unless Baker Hughes agrees to extend those dates. In addition, Baker Hughes has agreed to reserve manufacturing capacity for purposes of fabricating equipment to be supplied under the agreement. While we have executed the applicable purchase orders for the Plaquemines Project and the CP2 Project, we have not yet executed any such purchase orders for the CP3 Project or the Delta Project. If we do not execute applicable purchase orders by the applicable dates in the agreement, Baker Hughes may utilize the relevant manufacturing capacity for other purposes and delivery of equipment by Baker Hughes under the agreement could be delayed. Based on our anticipated project schedule, we currently expect that we will be in a position to deliver the purchase orders for the CP3 Project, and the purchase orders for the Delta Project to Baker Hughes by the applicable deadlines in the Baker Hughes Master Agreement, as such deadlines may be amended from time to time. However, if a project is delayed for any reason (including the reasons described elsewhere in this “Risk Factors” section), Baker Hughes’ obligations with respect to the remaining equipment to be delivered would expire unless we either (i) deliver the applicable purchase order and commence making payments on the agreed schedule, or (ii) agree with Baker Hughes on an extension of the applicable deadline under the agreement. There can be no assurance that we would be able to negotiate any such extension on terms that are acceptable to us or at all, or that we will have the financial resources to make the scheduled payments with respect to a purchase order prior to commencement of construction and financing of the relevant project.

The termination of any of the definitive agreements we have entered into with contractors, or any change to the pricing under those agreements, could have a material impact on our ability to complete the Plaquemines Project, the CP2 Project, the CP3 Project or the Delta Project on our anticipated schedule or budget, or at all.

Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.

Our cost estimates for LNG facilities, related equipment and components, natural gas pipelines, LNG tankers, and other natural gas liquefaction and export facilities have been, and continue to be, subject to change due to many factors outside of our control. Such factors include, among other things, (i) inflationary factors, (ii) changes in commodity prices (particularly nickel and steel), (iii) escalating labor costs, (iv) supply chain availability, including the availability of critical components and increased costs to locate and procure alternatives, (v) labor disputes, (vi) tariffs, (vii) unexpected delays in construction or commissioning, and (viii) unexpected repair, replacement, rectification, or warranty work. Such factors have in the past resulted in, and may in the future result in, among other things, delays in construction or commissioning, repair or warranty

 

44


Table of Contents

work, cost overruns, and/or change orders under or amendments to existing or future construction contracts. Further, we may decide or be forced to enter into amendments to construction and/or supply contracts or submit change orders to the applicable contractor that could result in longer construction periods, higher costs or both. We may also decide or be forced to expend additional funds in order to maintain construction schedules, complete construction and commissioning, or comply with existing or future environmental or other regulations. Additionally, our estimated costs for our projects do not include estimated costs for any potential bolt-on expansion opportunities that we may pursue in the future. As a result, costs to achieve completion of LNG facilities, related equipment and components, natural gas pipelines, LNG tankers, and other natural gas liquefaction and export facilities may be higher, potentially materially, than our cost estimates. In the event we experience any such increases in estimated costs, delays or both, the amount of funding needed to complete an LNG facility, a phase thereof, related equipment and components, natural gas pipelines, LNG tankers, and other natural gas liquefaction and export facilities, could exceed our available funds and result in our failure to complete such projects or assets and thereby negatively impact our business and limit our growth prospects.

We currently estimate that the total project costs for the Calcasieu Project will be approximately $9.8 billion, including EPC contractor profit and contingency, owners’ costs and financing costs, and we expect that the remaining project costs to achieve COD for the Calcasieu Project will be funded with cash we hold in reserve accounts pursuant to our project financing arrangements, which is reflected as restricted cash in our financial statements. However, there is no assurance as to whether the amount of cash held in these accounts will be sufficient to complete the construction of the Calcasieu Project and achieve COD, including, for example as a result of any additional unforeseen costs related to ongoing repairs and replacements or an unsuccessful outcome of any of our pending legal proceedings. See “—We will require significant additional capital to construct and complete certain of our projects, and we may not be able to secure such financing on time with acceptable terms, or at all, which could cause delays in our construction, lead to inadequate liquidity and increase overall costs” and “—Risks Relating to Regulation and Litigation—If we are unsuccessful in our current and any potential future arbitration proceedings with our customers, the amounts that we are required to pay may be substantial and certain of our post-COD SPAs may be terminated, which may lead to an acceleration of all our debt for the relevant project.”

We currently estimate that the total project costs for the Plaquemines Project will be approximately $22 billion to $23 billion, including EPC contractor profit and contingency, owners’ costs and financing costs, of which approximately $17.7 billion had been paid for as of September 30, 2024. This estimate is based in part on the target cost determined pursuant to the Plaquemines EPC Contracts and reflects increases related to, among other things, inflationary factors and efforts to maintain the project schedule while also reserving additional contingency funds (without giving effect to any commissioning cargo proceeds that may be utilized for project costs). Since FID of Phase 2 of the Plaquemines Project, VGLNG has made several incremental equity contributions to VGPL in an aggregate amount equal to $2.35 billion to address such increases in estimated total project costs, and we may be required to make additional incremental equity contributions to the extent total project costs exceed the low-end of the range of estimated total project costs above and that such costs exceed the available project-level debt and equity financing and net proceeds from the sale of commissioning cargos. Pursuant to the Plaquemines Credit Facilities, if such contributions have been utilized to pay project costs for the Plaquemines Project, they are reimbursable by VGPL to VGLNG at our election upon satisfaction of certain conditions under the Plaquemines Construction Term Loan. The costs to achieve completion of the Plaquemines Project may be subject to further increases, which could be material, as a result of many factors outside of our control as described above. As a result, we may need to make additional equity contributions or raise additional project-level equity financing or debt financing in the future to fund any such increase in estimated total project costs that exceed our current contingency, and any such additional contributions or funding could be significant.

We currently estimate that the total project costs for the CP2 Project, the CP3 Project and the Delta Project will range from approximately $27 billion to $28 billion, $44 billion to $45 billion and $37 billion to $38 billion, respectively, in each case including EPC contractor profit and contingency, owners’ costs and financing costs, substantially all of which have not yet been funded. These estimates are based primarily upon our construction cost experiences with the Calcasieu Project and the Plaquemines Project, the pricing included in the CP2 Phase 1

 

45


Table of Contents

EPC Contract, and reflect the current inflationary environment as well as the fact that the pipelines for the CP2 Project, the CP3 Project and the Delta Project are expected to be longer and more expensive than the pipelines for the Calcasieu Project and the Plaquemines Project. The CP3 and Delta projects are also expected to be larger in scale than our first three projects, with expected nameplate capacity of 30.0 mtpa and 24.4 mtpa, respectively. Moreover, no substantial construction work has been undertaken on either the CP3 Project or the Delta Project to date, we have not yet entered into a number of material contracts (including an EPC contract for Phase 2 of the CP2 Project, or any portion of the CP3 Project or the Delta Project) for the CP2 Project, the CP3 Project or the Delta Project, and our actual costs could vary significantly from our preliminary estimates depending on the terms we may agree to for those contracts. There is no guarantee that we will be able to enter into the necessary contracts to construct the CP2 Project, the CP3 Project, the Delta Project, or any other natural gas liquefaction and export facility we may decide to develop in the future, on the same or substantially similar terms as the Calcasieu EPC Contract, the Plaquemines EPC Contracts or the CP2 Phase 1 EPC Contract. As a result, our cost estimates are only an approximation of the actual costs of construction and financing for the CP2 Project, the CP3 Project and the Delta Project.

Further, the cost reimbursement arrangements under our existing EPC contracts provide that the EPC contractor will be reimbursed for all reimbursable costs incurred in connection with the relevant work, and while the EPC contractor’s profit margin will decrease as the amount of cost overrun increases, we are obligated to reimburse the EPC contractor for all reimbursable costs incurred under the EPC contract. However, EPC contracts that we enter into in the future may not include similar cost protections, which could lead to greater cost overruns for our other projects. Any increase in the construction costs for any of our projects could have an adverse impact on our business plan and the viability of the relevant project, and could have a material adverse effect on our current or future business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. See also “—Various economic and political factors, including opposition by environmental or other public interest groups, could negatively affect the timing or overall development, construction and operation of our projects, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, liquidity and prospects.”

Our cost estimates with respect to any LNG facilities, related equipment and components, natural gas pipelines, LNG tankers, regasification facilities and other natural gas liquefaction and export facilities (including any expansion of an existing facility) we may decide to develop in the future would be subject to similar uncertainties and potential changes. For example, our cost estimates may continue to increase as we negotiate and finalize agreements with contractors for any such project. Any increases in the construction costs for any of our projects could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Delays in the construction of our projects beyond the estimated development periods could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Our current schedule for the completion of our projects may turn out not to be achievable. For example, our ability to complete our projects on the anticipated schedule is dependent upon our receipt and maintenance of required regulatory approvals and permits and upon various activities being completed by our contractors. See “—We are dependent on our contractors for the successful completion of our projects and any bolt-on expansion opportunities at our projects that we may pursue, and any failure by our contractors to perform their contractual obligations could have a material adverse impact on our projects” and “—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.” Any significant construction or commissioning delay could increase the total cost of the relevant projects and would cause a delay in the completion of the construction of our projects, any of which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

 

46


Table of Contents

In addition, delays in the construction of our projects beyond the estimated development periods could have a material adverse effect on our contracts. For example, we have experienced unexpected delays in commissioning the Calcasieu Project related to certain necessary repairs and replacements. As a result, we expect COD for the Calcasieu Project to be later than originally forecasted while significant work related to commissioning, carryover completions, rectification, and certain other items is being completed. Although we are currently generating revenue from sales of LNG commissioning cargos from the Calcasieu Project prior to commencing commercial operations, we will not generate any revenues or cash flows under our post-COD SPAs (including the Intercompany Excess Capacity SPAs) until we have achieved COD at the project. Additionally, a failure to achieve the project completion date for a project by a date certain may result in an event of default under the related project financing, and, based on a cross-default, an event of default under our other financing agreements for that project or otherwise. Any such event of default would entitle the applicable debtholders to exercise certain remedies, including to accelerate the debt obligations under their respective debt instruments and to foreclose against all collateral that secures such debt, representing substantially all assets of the relevant project, which could seriously harm our business and lead to a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. See “—Risks Relating to Our Indebtedness and Financing—Upon the occurrence of an event of default under our existing and future indebtedness, our lenders and the holders of our debt securities could elect to accelerate all or a portion of our debt. A delay in COD of the Calcasieu Project or Phase 1 or 2 of the Plaquemines Project beyond a certain deadline could also result in an event of default under the Calcasieu Pass Credit Facilities or the Plaquemines Credit Facilities, respectively, and/or certain investors exercising step-in rights to control, directly or indirectly, certain of our subsidiaries and the Calcasieu Project.”

Any delay in a project’s ability to produce and load LNG for sale or delay in the completion of our projects could cause a delay in the receipt of proceeds projected from sales of LNG commissioning cargos and/or from post-COD SPAs or lead to a loss of one or more customers in the event of significant delays. In particular, each of our post-COD SPAs provides that the counterparty may terminate that SPA in the event that such project has not achieved COD by the relevant deadlines, and such counterparties could also bring claims for contractual damages. See “—Risks Relating to Regulation and Litigation—We are involved and may in the future become involved in disputes and legal proceedings” and “—Risks Relating to Regulation and Litigation—If we are unsuccessful in our current and any potential future arbitration proceedings with our customers, the amounts that we are required to pay may be substantial and certain of our post-COD SPAs may be terminated, which may lead to an acceleration of all our debt for the relevant project.”

We are dependent on third party vendors and service providers to provide certain services and equipment to our projects.

We rely on third party vendors and service providers to provide certain services, supplies, products and equipment to our projects. We have entered into agreements with these third parties in connection with such services, supplies, products and equipment. However, the ability of our third party vendors and service providers to perform successfully under their agreements is dependent on a number of factors, including their ability to:

 

   

maintain their own financial condition, including adequate working capital, and their ability to pay debt service and other liabilities;

 

   

accurately estimate certain costs;

 

   

meet quality or performance standards for third party equipment;

 

   

procure equipment and supplies;

 

   

execute requisite work and services efficiently; and

 

   

attract, develop and retain skilled personnel.

 

47


Table of Contents

If any third party vendor or service provider is unable or unwilling to perform according to the terms of its respective agreement for any reason or terminates its agreement, we may need to engage a substitute vendor or service provider. This would likely result in significant project delays and increased costs, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Various economic and political factors, including opposition by environmental or other public interest groups, could negatively affect the timing or overall development, construction and operation of our projects, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, liquidity and prospects.

Our ability to commence liquefaction operations and produce LNG at our projects (other than the Calcasieu Project and the Plaquemines Project, which commenced production of LNG in early 2022 and in December 2024, respectively) or any other natural gas liquefaction and export facility (or expansion of an existing facility) we may decide to develop in the future is dependent on the construction of the relevant facility (or expansion thereof), which will require the expenditure of significant amounts of capital that may exceed our estimates. The development and construction of our projects and any other natural gas liquefaction and export facilities (or expansion of an existing facility) that we may decide to develop in the future takes a number of years and may be delayed by factors such as:

 

   

our ability to obtain or maintain necessary permits, licenses and approvals from regulatory agencies and third parties that are required to construct or operate the relevant project;

 

   

our ability to enter into final ground leases for the relevant project site;

 

   

the identification of any adverse issues with respect to the relevant project site;

 

   

our ability to obtain right-of-way permits, servitudes or other similar property rights necessary to construct the pipelines required to interconnect the relevant project site with natural gas suppliers;

 

   

our ability to administer the Calcasieu EPC Contract, the Plaquemines EPC Contracts, and the CP2 Phase 1 EPC Contract and to successfully negotiate a definitive agreement with EPC contractors for Phase 2 of the CP2 Project, the CP3 Project, the Delta Project and any future projects we develop, as well as with other advisors, contractors and consultants necessary for the development and construction of the relevant project in a timely manner for each of our projects;

 

   

our ability to maintain or secure definitive post-COD SPAs for an adequate portion of the expected nameplate capacity of the CP2 Project, the CP3 Project, the Delta Project or any future projects we develop to support an FID for each such project;

 

   

our ability to secure necessary additional capital or financing on satisfactory terms, or at all, to develop the CP2 Project, the CP3 Project and the Delta Project and any additional projects;

 

   

the discovery of environmental conditions on the relevant project site that require investigation, remediation or other changes to the relevant project;

 

   

failure by our contractors to fulfill their obligations under their contracts relating to the development and construction of the relevant project, or disagreements with them over their contractual obligations;

 

   

as construction progresses, we may decide or be forced to submit change orders to our contractors that could result in longer construction periods and higher than anticipated construction expenses;

 

   

force majeure events, natural or man-made disasters, terrorist attacks or sabotage;

 

   

shortages of materials or delays in the delivery of materials;

 

   

weather conditions and impacts from potential climate change, hurricanes, severe weather events and other catastrophes, such as explosions, fires, floods and accidents;

 

   

local and general economic and infrastructure conditions;

 

48


Table of Contents
   

political unrest or local community resistance or resistance by environmental groups and other advocates or impacts to indigenous peoples or impact by indigenous people to the development of the relevant project due to health, safety, environmental, or security or other concerns;

 

   

our ability to attract sufficient skilled and unskilled labor, the existence of any labor disputes, our ability to maintain good relationships with our contractors in order to construct the relevant project within the expected parameters and the ability of those contractors to perform their obligations;

 

   

economic downturns, increases in interest rates or other events that may affect the availability of sufficient financing for LNG projects on commercially reasonable terms;

 

   

decreases in the price of LNG, which might decrease the expected returns relating to investments in LNG projects; and

 

   

other risks inherent to the construction, expansion and operation of LNG facilities and other natural gas liquefaction and export facilities.

Many of these factors are outside of our control. For example, in a December 11, 2023 letter to the DOE, a coalition of more than 200 environmental groups called on the DOE to deny the export license for Non-FTA Nations for the CP2 Project on the alleged basis that it is not in the public interest. In January 2024, the Biden administration announced a temporary pause on new authorizations of natural gas exports to non-FTA Nations while the DOE conducts studies to update its analyses regarding whether the exports are “not inconsistent with the public interest.” See “—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

More generally, the regulatory approval process for many LNG and natural gas infrastructure projects has become increasingly slower and more difficult, due in part to federal, state and local concerns related to natural gas exploration and production, pipeline activities and associated environmental impacts, and increased opposition to the natural gas industry and related infrastructure. Furthermore, regulatory approvals and authorizations, even when obtained, have increasingly been subject to judicial challenge by activists requesting that issued approvals and authorizations be stayed, reversed, and vacated. Increased opposition and regulatory challenges may harm our ability to obtain and maintain necessary regulatory approvals. For example, on November 27, 2024, in response to project opponents challenging FERC’s authorization for the CP2 Project, FERC issued an order on rehearing that generally rejected the arguments opposing the CP2 Project and noted that it remains confident in the authorization order, but decided to partially “set aside” its prior analysis to initiate a supplemental environmental review of certain discrete potential impacts of the project. As a result, FERC stated that it will not issue authorizations to proceed with construction until FERC issues a further merits order. The opponents of the CP2 Project have also appealed the initial FERC authorization of the CP2 Project to the U.S. Court of Appeals for the D.C. Circuit.

There can be no assurance that our existing or future regulatory approvals will not be subject to other legal challenges, or that such approvals will not be re-examined vacated, withdrawn, overturned, altered or otherwise modified in a manner adverse to the development, construction or operation of one or more of our projects or to our business more generally. If we are required to modify our activities as a result of any changes to our existing regulatory approvals, the impact could increase our project costs, delay our project timelines, affect our ability to complete our planned projects, or result in claims from third parties if we are unable to meet our commitments under our pre-existing commercial agreements, all of which could have a material adverse effect on our business. Any delay in completion of our projects that prevents us from producing and loading LNG when anticipated would also cause a delay in the receipt of revenues therefrom, potentially require us to pay damages to selected customers with whom we have entered into definitive SPAs, or, in the event of significant delays beyond certain time periods, permit customers to terminate their contractual obligations to us. See “—Delays in the construction of our projects beyond the estimated development periods could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.”

 

49


Table of Contents

In addition, the successful completion of our projects is subject to the risk of cost overruns, schedule delays, weather disruptions, labor disputes and other factors, any of which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. See also “—The construction of our projects, and our operations, are subject to significant hazards and uninsured risks, one or more of which may create significant liabilities and losses for us” and “—Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.”

Our business could be materially and adversely affected if we do not secure the right or if we lose the right to situate certain lateral pipelines, longer-haul pipelines or any other pipeline infrastructure for any of our projects on property owned by third parties, or if we do not complete the construction of those pipelines in a timely fashion.

We expect to obtain access to the natural gas required for the operation and commissioning process for our projects through certain lateral and longer-haul pipeline connections that we plan to construct as part of those projects, each of which will connect the relevant LNG facility to one or more third-party pipelines. While the lateral pipelines for both the Calcasieu Project and the Plaquemines Project are complete, much of this contemplated pipeline infrastructure has not been completed. As we are expanding our development footprint with the CP2 Project, the CP3 Project and the Delta Project, these projects’ production capacities will require natural gas volumes that necessitate the construction of longer interstate and intrastate pipelines that provide incremental access and delivery capability from the Permian, Haynesville, Western Haynesville, Eagle Ford, mid-continent shale, and other formations. At their expected peak production capacity, we expect these three development stage projects will require approximately 4.3, 6.5 and 5.3 bcf/d of gas supply, respectively. We plan to construct significant 48 inch compressed pipeline infrastructure, both independently and in partnership with certain qualified third parties, sufficient to source the required natural gas for these projects from primarily the Permian, Haynesville and Western Haynesville shale plays. Timely completion of such pipelines will be subject to numerous risks, such as interface risks with our third-party partners, weather delays, accidents, inability to obtain required rights-of-way and servitudes, and regulatory approvals. See “Business—Key, Complementary Assets—Natural Gas Supply and Transportation.”

We do not expect to own or lease the vast majority of the tracts of land on which we expect to construct the pipeline infrastructure that will connect our projects to third-party pipelines and other sources of natural gas. As a result, we need to secure servitudes, rights-of-way and similar rights necessary for the construction of that pipeline infrastructure. Although we have obtained permanent servitudes in respect of all of the land on the TransCameron Pipeline route for the Calcasieu Project and the Gator Express Pipeline route for the Plaquemines Project, certain tracts in respect of which we have obtained such rights are currently burdened by mortgages that would be superior to our rights. While the servitudes we obtain generally contain clauses that require the relevant landowners to use commercially reasonable efforts to provide us with subordination, non-disturbance and attornment agreements, or the SNDAs, if we request them, there can be no assurance that any such SNDAs, or any other measures we take, will result in us having adequate real property rights with respect to these tracts. Moreover, with respect to the other pipelines that we plan to develop, we have not yet obtained all of the rights necessary to construct the pipeline infrastructure expected to connect those projects to third-party pipelines and other sources of natural gas, and there can be no assurance that we will be able to obtain the necessary property rights on terms satisfactory to us, or at all.

As a result of these factors, our pipeline infrastructure for the CP2 Project, the CP3 Project and the Delta Project is subject to the possibility of increased costs to obtain necessary land use rights. If we were unable to obtain those rights or if we were to lose any such rights with respect to a project, or if we were required to relocate any of our pipeline infrastructure, our business could be materially and adversely affected.

 

50


Table of Contents

There is no assurance that our projects will receive the local government and community support required for construction.

The development and construction of our projects requires support and approval from local governments with jurisdiction over the project sites and support from the communities in which they are located. While we believe we have requisite local government and community support in Cameron Parish and Plaquemines Parish, where our projects our located, there is no assurance that we can maintain such support or that we will receive such support for other projects we may develop in the future. Any failure to obtain or maintain the requisite local government and community support for our projects, or for any other natural gas liquefaction and export facility we may decide to develop in the future, could have a material adverse effect on our ability to develop and construct that project on our anticipated schedule, or at all.

Our real property rights in the sites for our projects or any other natural gas liquefaction and export facilities that we may decide to develop in the future may be adversely affected by the rights of others that are superior to those of the grantors of our real property rights.

The Calcasieu Project, the Plaquemines Project, the CP2 Project, the CP3 Project, the Delta Project, and any other natural gas liquefaction and export facilities (including any expansion of existing facilities) that we may decide to develop in the future are likely to be, located on land subject to long-term servitudes, leases, rights of way and similar agreements with landowners. The ownership interests in the land subject to these servitudes, leases, rights-of-way and similar agreements may be subject to mortgages securing loans or other liens (such as tax liens) and other servitudes, lease rights and rights-of-way of third parties that were created prior to our servitudes, leases and rights-of-way. As a result, certain of our rights under these servitudes, leases or rights-of-way may be subject, and subordinate, to the rights of those third parties.

We perform title searches, obtain title insurance and enter into non-disturbance agreements to protect ourselves against these risks. Such measures may, however, be inadequate to protect our operating projects against all risk of loss or impairment of our rights to use the land on which the Calcasieu Project, the Plaquemines Project, the CP2 Project, the CP3 Project, the Delta Project or any future natural gas liquefaction and export facilities we may decide to develop are located.

Any such loss or curtailment of our rights to use the land on which our projects or any other future project is located, and any increase in rent due on such lands, could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock and could also adversely affect our ability to secure necessary additional capital for the relevant project.

The natural gas liquefaction system and mid-scale design we utilize at our projects are the first of such sized modules developed by us and Baker Hughes, and there can be no assurance that these modules, or our projects, will achieve the level of performance or other benefits that we anticipate over the long term.

We are constructing our projects using a natural gas liquefaction system provided by Baker Hughes that is deployed in a unique mid-scale, factory-built configuration that we developed. While Baker Hughes has developed liquefaction systems utilizing both larger and smaller modules before, the specific liquefaction modules that we are using are the first of such sized modules produced by Baker Hughes, and accordingly the configuration, production, transportation, installation and commissioning of such sized modules has not yet been tested in LNG projects, except for the Calcasieu Project and the Plaquemines Project. As a result, there may be issues with respect to this design that have not yet been identified, notwithstanding the current production of LNG at the Calcasieu Project, that could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. While Baker Hughes has an obligation to ensure the liquefaction systems meet minimum performance guarantees, there can be no assurance that the liquefaction system is able to satisfy the minimum performance guarantees or maintain such performance guarantees throughout the operating life of a facility.

 

51


Table of Contents

We have the right under the Baker Hughes Master Agreement to require Baker Hughes to enter into a long-term service agreement on specified terms with respect to long term maintenance, repair, and servicing of the liquefaction, power, and booster compressor equipment it supplies. While we have entered into a long-term service agreement with Baker Hughes for the Calcasieu Project, under which Baker Hughes guarantees the minimum performance and operating availability of certain liquefaction and power systems it supplies, we have not yet negotiated the final terms for any such long-term service agreement for the Plaquemines Project or any other project. Notwithstanding our rights under the Baker Hughes Master Agreement, there can be no assurance that we will enter into the long-term service agreement with Baker Hughes on the same terms as we currently anticipate. If we encounter issues with the new technology, including, for example, higher operating or maintenance expenses, lower performance standards or more downtime than we currently anticipate, our projects may not be able to produce the quantity or volume of LNG we anticipate and our projects may be delayed and the financial viability of our projects may be adversely impacted. Any of these factors could have a material adverse effect on our business, financial condition, operating results, liquidity, prospects and the price of our Class A common stock.

The phased commissioning start-up of our projects will subject us to additional risks.

The unique configuration of our LNG projects necessitates a phased commissioning start-up process for each of our projects (and phases thereof) that will generally result in a longer commissioning process. The length of any commissioning process depends on a number of factors related to equipment performance and the ability to establish reliable and safe operations for that equipment and the facility as a whole. See “Risks Relating to Our Projects and Other Assets—Our ability to generate proceeds from sales of commissioning cargos is subject to significant uncertainty and volatility in such proceeds. Historical proceeds from such sales at the Calcasieu Project, which has had an extended commissioning period due to unanticipated challenges with equipment reliability that we are in the process of remediating, may not be indicative of the duration of the commissioning period or the amount of the proceeds for any future period or for any of our other projects”. For example, once we have sufficient power to operate the first pre-treatment unit, and the first LNG storage tank and first gas pre-treatment unit have been installed for a particular project, we plan to begin the commissioning start-up of the relevant equipment on a phased basis. This sequential commissioning of the liquefaction blocks, power island system, pre-treatment system, and other equipment for a project is subject to several risks, some of which may be unknown to us.

For example, the simultaneous construction of a particular LNG facility and production of LNG at that facility could subject us and our third-party contractors to additional safety hazards, as well as additional costs related to the management of those safety hazards during the phased commissioning start-up of a facility. To successfully implement our phased commissioning start-up, our EPC contractors will be required to develop and implement a safe work plan. Furthermore, we will require additional regulatory approvals from FERC, including approval of our EPC contractor’s safe work plan, in order to implement our phased commissioning start-up at a facility before construction has been completed. Any delays in implementing any of the measures required for the phased start-up of our facilities or in obtaining any necessary regulatory approvals, and any additional costs associated with the phased start-up of our facilities, could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We are and will be relying on third-party engineers to estimate the future capacity ratings and performance capabilities of our projects, and these estimates may prove to be inaccurate.

We are and will be relying on third parties, principally the construction contractors, for the design and engineering services underlying our estimates of the future capacity ratings and performance capabilities of our projects. If any of our liquefaction facilities for our projects, when completed, fails to have the capacity ratings and performance capabilities that we intend, the estimates set forth in this prospectus may not be accurate. Failure of any of our liquefaction facilities for our projects to achieve our intended capacity ratings and

 

52


Table of Contents

performance capabilities could prevent us from satisfying the performance tests required in order to achieve COD start dates under our post-COD SPAs and cause the quantity of LNG we produce to fall short of our contractual delivery obligations to customers and could have a material adverse effect on our business, contracts, operating results, financial condition, cash flow, liquidity, financing requirements, prospects and the price of our Class A common stock. Further, we will not generate any revenues or cash flows under our post-COD SPAs (including the Calcasieu Foundation SPAs) or from sales to third parties of excess capacity covered by the Intercompany Excess Capacity SPAs, in each case until we have achieved COD for the relevant project.

Additionally, a failure to achieve the project completion date for a project by a date certain may result in an event of default under the related project financing, and, based on a cross-default, an event of default under our other financing agreements for that project or otherwise. Further, under certain financing agreements we may be required to (i) maintain in effect all material project agreements, including the relevant EPC contract, for a particular project and (ii) comply in all material respects with their payment and other material obligations under the material project agreements for such project, and any breach of such requirements may, after any applicable cure periods, result in an event of default under our other financing agreements for that project or otherwise. Any such event of default would entitle the applicable debtholders to exercise certain remedies, including to accelerate the debt obligations under their respective debt instruments. See “—Delays in the construction of our projects beyond the estimated development periods could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.”

Construction and operations of natural gas pipelines and lateral pipeline connections for our projects are subject to a number of regulatory approvals, development risks, operational hazards and other risks, which could cause cost overruns and delays and could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We have completed the construction of only one of our natural gas pipeline projects, the TransCameron Pipeline. One of our other pipelines, the Gator Express Pipeline, is nearly complete after achieving mechanical completion in October 2023, introducing natural gas for commissioning activities in April 2024, and placing its laterals in service in May 2024 and December 2024. Construction and operations of our future, planned natural gas pipelines and pipeline connections for our projects, including the CP Express natural gas pipeline, the pipeline required for the CP3 project and the Delta Express natural gas pipeline, are subject to the risks of delay or cost overruns inherent in any construction project resulting from numerous factors, including, but not limited to, the following:

 

   

failure to obtain and maintain relevant approvals and permits from governmental and regulatory agencies;

 

   

difficulties or delays in obtaining, or failure to obtain, sufficient equity or debt financing on reasonable terms;

 

   

difficulties in engaging qualified contractors necessary for the construction of natural gas pipelines and lateral pipeline connections for any of our projects;

 

   

shortages of equipment, material or skilled labor;

 

   

natural disasters and catastrophes, such as hurricanes, explosions, fires, floods, industrial accidents and terrorism;

 

   

unscheduled delays in the delivery of ordered materials;

 

   

EPC productivity factor realization, work stoppages and labor disputes;

 

   

difficulties or delays in obtaining, or failure to obtain, sufficient real property interests on which to construct and locate the pipelines and associated facilities;

 

53


Table of Contents
   

unexpected or unanticipated need for additional improvements;

 

   

unexpected additional material quantities and labor hours; and

 

   

adverse general economic conditions.

Delays beyond the estimated development periods, as well as cost overruns, could increase the cost of completion beyond the amounts that are currently estimated, which could require us to obtain additional sources of financing to fund the activities. Any delay in completion of the pipelines may also cause a delay in commencement of commercial operations of our projects even if the projects are substantially complete for commercial operations. As a result, any significant construction delay in construction of the natural gas pipelines and lateral pipeline connections, whatever the cause, could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

If third-party pipelines and other facilities interconnected to our pipelines and facilities are or become unavailable to transport natural gas or if there are any reductions in the capacity of, or the allocations to, interconnecting third-party pipelines, this could cause a reduction of volumes transported to our facilities and could have a material adverse effect on our business, financial condition, operating results, liquidity, prospects and the price of our Class A common stock.

We depend and will continue to depend upon third-party pipelines and other facilities interconnecting with our projects to provide material gas delivery options to our liquefaction and export facilities. We have entered into multiple agreements with various pipelines for the transport of natural gas to the Calcasieu Project and the Plaquemines Project. The transport of natural gas to the Calcasieu Project and the Plaquemines Project has been secured through a portfolio of approximately 20-year transportation arrangements, including agreements with Texas Eastern Transmission LP, ANR Pipeline Company, Sabine, Columbia Gulf, and Tennessee Gas Pipeline. We are also in the process of contracting for, or developing, the required transportation capacity for our other projects. We do not have any control over the operation, development, expansion or maintenance of these pipelines or certain other third-party pipeline and pipeline facilities that may be interconnected with our projects in the future.

The design, construction and operation of natural gas pipelines are highly regulated activities. Approvals of FERC under Section 7 of the NGA, as well as several other material governmental and regulatory approvals and permits, are required in order to construct and operate an interstate natural gas pipeline, and those approvals may be subject to judicial appeals. Neither we nor our SPA customers have any control over the ability of third-party pipelines to obtain, maintain or comply with any such regulatory approvals and permits.

Additionally, the capacity on interconnecting pipelines may not be sufficient to accommodate additional liquefaction trains we may construct if we undertake an expansion of our project facilities. Further, if we need to replace one or more of our interconnection agreements or enter into additional agreements, we may not be able to do so on commercially reasonable terms or at all.

If we are unable to secure any necessary pipeline interconnections, or if any third-party pipelines or pipeline connections that we currently depend upon were otherwise to become unavailable for current or future volumes of natural gas due to a failure to obtain or maintain regulatory approvals or permits, repairs, damage to the facility, lack of capacity or any other reason, our ability to continue shipping natural gas from producing regions to our projects could be restricted, which could have a material adverse effect on our business and operations, and on our ability to perform under the SPAs.

Delays in deliveries of newbuild or acquired LNG tankers, and increases in price or building costs, could harm our operating results.

The delivery of newbuild LNG tankers to us could be delayed, not completed or cancelled, which would delay or eliminate our ability to optimize contracts with spot and term customers seeking delivered LNG. The

 

54


Table of Contents

relevant shipbuilder or third-party seller could fail to deliver the newbuild LNG tankers or the relevant shipbuilding contract or acquisition agreement could be cancelled if the shipbuilder, the seller or we have not met certain obligations, including the failure to pay any remaining amounts required under such agreements. In addition, third-parties from whom we may charter LNG tankers may fail to deliver such LNG tankers to us, or such deliveries could be delayed. If delivery of any newbuild LNG tankers currently contracted to be acquired, or any LNG tanker we contract to charter on a third-party basis, or acquire or charter in the future, is materially delayed, it could adversely impact our business and we may not be able to realize the anticipated benefits of operating our LNG tanker fleet.

Our receipt of newbuilds could be delayed, cancelled or otherwise not completed because of, among other things, quality or engineering problems or failure to deliver the LNG tanker in accordance with the specifications, changes in governmental regulations or maritime self-regulatory organization standards, delays to delivery of equipment by third-party suppliers, work stoppages or other labor disturbances at the shipyard, bankruptcy or other financial or liquidity problems of the shipbuilder, a backlog of orders at the shipyard, political or economic disturbances in the country or region where the vessel is being built, weather interference or catastrophic events, shortages of or delays in the receipt of necessary construction materials, such as steel, and our inability to finance the purchase of the LNG tanker.

In addition, the contracts for newly built vessels subject us to counterparty risk. The ability and willingness of each of our counterparties to perform its obligations under a contract with us will depend on a number of factors that are beyond our control, including, among other things, general economic conditions, the condition of the LNG shipping industry, the overall financial condition of our counterparty, prevailing prices for LNG cargos, rates received for specific types of LNG tankers, and various expenses. If our counterparties fail to meet their obligations to us or attempt to renegotiate our agreements, if our counterparties fail to deliver an LNG tanker in accordance with the terms of the relevant contract, or if a counterparty otherwise fails to honor its obligations to us under a contract, we could sustain significant losses, which could have a material adverse effect on our business, financial condition, results of operations and cash flows.

Additionally, the final cost of the LNG tankers we have contracted to acquire could increase, pursuant to adjustment provisions included in the respective contracts. As of September 30, 2024, an aggregate of approximately $1.2 billion remains payable pursuant to our existing contracts to acquire the LNG tankers. We may decide to raise additional capital to fund our remaining payment commitments pursuant to such contracts. Our ability to obtain financing that may be used to provide additional funding to cover all of the costs for our LNG tankers will depend, in part, on factors beyond our control. Accordingly, we may not be able to obtain financing on terms that are acceptable to us, or at all, which could impact our ability to make payments under our contracts to acquire LNG tankers when due. Any failure to make payments under any existing or future contracts to acquire LNG tankers could cause delays in the delivery of our newbuild LNG tankers or could result in an event of default under our contracts for the acquisition of LNG tankers. In addition, if we are unable to make any payments under our existing contracts to acquire LNG tankers when due, we may lose our rights to acquire such LNG tankers as well as our right to be refunded certain amounts already paid pursuant to the applicable contracts.

Delays in the delivery, or shortfalls in the construction and acquisition of, our LNG tanker fleet, could require us to charter or subcharter third-party LNG tankers, which could expose us to additional liability and could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. See “—Management and operation of our LNG tanker fleet and the subcharter of third-party vessels will involve significant risks.”

Management and operation of our LNG tanker fleet and the subcharter of third-party vessels will involve significant risks.

Through certain wholly-owned subsidiaries, in addition to the two newbuild LNG tankers that have been delivered already, we have entered into contracts to acquire seven additional LNG tankers that are currently

 

55


Table of Contents

under construction and will be delivered on a rolling basis in 2025 and 2026, which will be used to provide additional optionality to spot and term customers and to service our single existing post-COD DPU SPA and any future SPAs where LNG is sold on a delivered basis. Following delivery of each of these LNG tankers, we plan to manage and operate such tankers through our subsidiaries. In addition, we have chartered, and anticipate that we will continue to charter, LNG tankers to supplement our wholly-owned fleet. We are in the process of building out our team to manage and operate our fleet of LNG tankers, and as a result we will be exposed to various new operational risks as we expand that team and grow our fleet of LNG tankers. We will also be exposed to operational risks where we subcharter third-party vessels. For example, we will be exposed to the following risks with respect to the operation of LNG tankers:

 

   

the Company’s limited track record with managing and operating our own LNG tanker fleet;

 

   

performing below expected levels of efficiency or capacity or required changes to specifications for continued operations;

 

   

breakdowns or failures of equipment or shortages or delays in the delivery of supplies;

 

   

risks related to operators and service providers of tanker or tugs used in our operations;

 

   

operational errors by us or any contracted facility, port or other operator of related infrastructure.

 

   

failure to maintain the required government or regulatory approvals, permits or other authorizations;

 

   

accidents, fires, explosions or other events or catastrophes;

 

   

a lack of adequate and qualified personnel to adequately crew and operate the LNG tankers;

 

   

potential labor shortages, work stoppages or labor union disputes;

 

   

our potential inability to recruit and retain a team to manage and operate our fleet of LNG tankers and any subchartered third-party vessels;

 

   

weather-related or natural disaster interruptions of operations;

 

   

pollution, release of or exposure to toxic substances or environmental contamination, including marine accidents and spills, affecting operations;

 

   

inability, or failure, of any counterparty to any fleet-related agreements to perform their contractual obligations;

 

   

a lack of demand for shipping services by our customers after we receive delivery of our LNG tankers or subcharter a third-party vessel;

 

   

failures to supply due to scheduled or unscheduled maintenance; and

 

   

potential changes to cabotage laws which may affect the ability of our LNG tankers and subchartered third-party vessels to engage in coastwise trade.

As a result, in addition to our current operational risks, we will be subject to risks related to the operation of LNG tankers, which operations are complex and technically challenging and subject to mechanical risks and problems. In particular, marine LNG operations are subject to a variety of risks, including, among others, marine disasters, piracy, bad weather, mechanical failures, environmental accidents, epidemics, grounding, fire, explosions and collisions, human error, and war and terrorism. An accident involving our cargos or any of our LNG tankers or subchartered third-party vessels could result in death or injury to persons, loss of property or environmental damage; delays in the delivery of cargo; loss of revenues; governmental fines, penalties or restrictions on conducting business; higher insurance rates; and damage to our reputation and customer relationships generally. Any of these circumstances or events could increase our costs or lower our revenues.

If our LNG tankers, or any vessels we subcharter, suffer damage as a result of such an incident, they may need to be repaired. Repairs and maintenance costs for LNG tankers are difficult to predict and may result in

 

56


Table of Contents

higher than anticipated operating expenses or require additional capital expenditures. The loss of earnings or costs to subcharter replacement tankers while these LNG tankers are being repaired could have a material adverse effect on our current or future business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

If one of our LNG tankers, or any vessels we subcharter, were involved in an accident with the potential risk of environmental impacts or contamination, the resulting media coverage and potential liability, including regulatory penalties, sanctions, fines and litigation, could have a material adverse effect on our reputation, our current or future business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. An accident involving one of our LNG tankers would also distract our management team. We expect our offshore operating expenses to depend on a variety of factors including crew costs, provisions, deck and engine stores and spares, lubricating oil, insurance, maintenance and repairs and shipyard costs, many of which are beyond our control. Other factors, such as increased cost of qualified and experienced seafaring crew and changes in regulatory requirements, could also increase operating expenditures.

If we fall short of our goals in acquiring, building or maintaining our LNG tanker fleet, we may be required to subcharter vessels from third parties. Additionally, our ability to subcharter vessels from third parties could be affected by potential shortages of LNG tankers worldwide. See “—Risks Related to the LNG Industry—There may be shortages of LNG tankers worldwide, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.” As the overall trends steer toward more regulation and more stringent operating requirements, we are subject to the risk that subchartered vessels we employ could fall out of compliance with such regulations. The terms of any charter agreement into which we may enter to substitute for shortfalls in our own LNG tanker fleet may require that we bear some or all of the associated costs with maintaining compliance with such regulations. While we believe we are appropriately situated to minimize this risk given the building of our own LNG tanker fleet, we cannot assure you that such factors will not have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Future occurrences of any of the foregoing or any other events of a similar or dissimilar nature could have a material adverse impact on our business, financial condition and results of operations.

The construction of our projects, and our operations, are subject to significant hazards and uninsured risks, one or more of which may create significant liabilities and losses for us.

The construction and operation of our projects is and will be subject to the inherent risks associated with these types of operations, including the following:

 

   

explosions, pollution, releases of toxic substances;

 

   

fires, hurricanes and adverse weather conditions and other weather-related interruptions of construction and/or operations;

 

   

facilities performing below expected levels of efficiency;

 

   

breakdown, failures or mechanical issues affecting our equipment;

 

   

operational errors by vessel or tug operators;

 

   

operational errors by us or any contracted facility operator; and

 

   

labor disputes.

The occurrence of any of these events could require us, or enable our counterparties, to declare a force majeure under our material construction contracts or other construction contracts or SPAs or otherwise could

 

57


Table of Contents

result in significant delays in commencement or interruptions of operations and/or in damage to or destruction of our facilities or damage to persons and property. In addition, our operations and the facilities and vessels of third parties on which our operations are dependent face possible risks associated with acts of aggression or terrorism.

We do not, nor do we intend to, maintain insurance against all of these risks and losses. We may not be able to maintain desired or required insurance in the future at rates that we consider reasonable. The occurrence of a significant event not fully insured or indemnified against could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We may enter into certain arrangements to share the use and operations of facilities among projects, which would require us to meet certain conditions under our project-level financing documents. Despite the protection provided by such financing documents, the nature of such sharing arrangements is not currently known and may limit our operational flexibility, use of land and/or facilities.

We are permitted under certain of our project-level financing documents to enter into sharing arrangements with one or more entities that are developing or own one or more liquefaction trains and related facilities among our various projects. Such sharing arrangements may involve sharing the use and capacity of land and facilities with such adjacent project owners, including pooling the capacity of liquefaction trains, sharing common facilities, such as power generating facilities, storage tanks and berths, and sharing capacity of the pipeline interconnections, to the extent permitted under the relevant financing documents. We may also, subject to regulatory approvals, transfer and/or amend previously obtained permits and other authorizations or applications such that they may be used by such other project owners with which we may have sharing arrangements.

As future arrangements that would only be fully determined if the circumstances arise, there is uncertainty as to the full scope and impact of these sharing arrangements. Our project-level financing documents require us to meet certain conditions in respect of such sharing arrangements. These sharing arrangements would be subject to quiet enjoyment rights for the relevant project owners.

Risks Relating to the LNG Industry

Competition in the LNG industry is intense, and certain of our competitors may have greater financial, engineering, marketing and other resources than we have.

We operate in the highly competitive area of LNG production, and we face intense competition from independent, technology-driven companies, national oil companies and major independent oil and natural gas companies and utilities. Certain of our competitors may have financial, engineering, marketing and other resources substantially greater than we have, and some of them are fully integrated oil and gas companies. Certain of these competitors also have longer operating histories, more development experience, greater name recognition, larger staffs, greater access to natural gas and LNG supply, and substantially greater financial, engineering, marketing and other resources than we do. In some cases, they may have also fully recouped the development and construction costs of their facilities. Our competitors’ superior resources or financial position could allow them to compete successfully against us, including by increasing their LNG production, decreasing their LNG prices, offering LNG transportation or otherwise. Our ability to compete in this highly competitive environment will depend in part upon our ability to successfully develop, construct and operate our projects and any other natural gas liquefaction and export facilities that we may develop in the future, and our ability to enter into SPAs or otherwise sell LNG. Increases in the production of LNG by our competitors, or decreases in their LNG prices, could have a material adverse effect on the viability of any of our planned projects and on our ability to compete with them successfully. If we are unable to compete successfully with these companies, our business, financial condition and results of operations could be adversely affected. See “Business—Competition.”

 

58


Table of Contents

We face competition based upon the international market price for LNG.

Our projects are and will be subject to the risk of LNG price competition at times when we need to replace any existing post-COD SPA, whether due to natural expiration, default or otherwise, and at times when we seek to sell or enter into additional SPAs with respect to our respective projects’ commissioning cargos and LNG that is produced in excess of the volumes required under our existing SPAs. Factors relating to competition may prevent us from entering into a new or replacement post-COD SPA on economically comparable terms as existing post-COD SPAs, or at all. Such an event could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. Factors which may negatively affect potential demand for LNG from our projects and any other natural gas liquefaction and export facilities that we may decide to develop in the future are diverse and include, among others:

 

   

increases in worldwide LNG production capacity and availability of LNG for market supply;

 

   

lower than expected global economic growth and decreased demand for energy, including LNG, or increases in demand for LNG but at levels below those required to maintain a price equilibrium with respect to the cost of supply;

 

   

increases in the cost to supply natural gas feedstock to our projects (see “—Cyclical or other changes in the demand for and price of LNG and natural gas may adversely affect our business and the performance of our customers and could have a material adverse effect on our business, contracts, financial condition, operating results, cash flows, liquidity and prospects and the price of our Class A common stock.”);

 

   

decreases in the cost of competing sources of natural gas or alternate fuels such as coal, heavy fuel oil and diesel;

 

   

decreases in the price of non-U.S. LNG, including decreases in price as a result of contracts indexed to lower oil prices;

 

   

increases in capacity and utilization of nuclear power, renewable power, and related facilities outside the United States;

 

   

political instability in foreign countries that import LNG, or strained relations between such countries and the United States; and

 

   

displacement of LNG by new discoveries of gas, pipeline natural gas or alternate fuels in locations where access to these energy sources is not currently available.

Failure of LNG exported from the United States, including from our projects, to remain a competitive source of energy for international markets could adversely affect the LNG business of our customers, which could have a material adverse effect on their ability and willingness to perform under their post-COD SPAs with us or otherwise contract with us, and on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Operations at our projects will be dependent upon the ability of our customers to deliver LNG supplies from the United States, including our projects, which is primarily dependent upon LNG being a competitive source of energy internationally. The success of our business plan and the commercial operations of our projects, or any other natural gas liquefaction and export facility that we may decide to develop in the future, is dependent, in part, on the extent to which LNG can, for significant periods and in significant volumes, be supplied from North America and delivered to international markets at a lower cost than the cost of alternative energy sources. Through the use of improved exploration technologies, additional sources of natural gas may be discovered outside the United States, which could increase the available supply of natural gas outside the United States and could result in natural gas in those markets being available at a lower cost than LNG exported to those markets.

Political instability in foreign countries that import or export natural gas, or strained relations between such countries and the United States, may also impede the willingness or ability of LNG purchasers or suppliers and

 

59


Table of Contents

merchants in such countries to import LNG from the United States. Furthermore, some foreign purchasers or suppliers of LNG may have economic or other reasons to obtain their LNG from, or direct their LNG to, non-U.S. markets or from or to our competitors’ liquefaction facilities in the United States. Conversely, future policy change in laws or regulation in the United States could restrict or limit natural gas exports to certain countries or in general.

In addition to natural gas, LNG also competes with other sources of energy, including coal, oil, nuclear, hydroelectric, wind and solar energy. LNG from our projects also competes with other sources of LNG, including LNG that is priced to indices other than Henry Hub. Some of these sources of energy may be available at a lower cost than LNG from our projects in certain markets. The cost of LNG supplies from the United States, including our projects, may also be impacted by an increase in natural gas prices in the United States. Although our customers may elect not to incur these costs by not lifting, or electing not to take delivery of certain scheduled LNG cargos, they are obligated to pay the fixed facility charge under the relevant SPA for their scheduled quantities. However, such commercial conditions could cause customers to seek alternatives to satisfying this obligation under their SPAs.

As a result of these and other factors, LNG may not be a competitive source of energy internationally. The failure of LNG to be a competitive supply alternative to local natural gas, oil and other alternative energy sources in markets accessible to our customers could adversely affect the ability of our customers to deliver LNG from the United States or from our projects on a commercial basis, which could have a material adverse effect on their ability and willingness to perform under their post-COD SPAs with us or contract with us with respect to the sales of our commissioning cargos or the excess capacity covered by the Intercompany Excess Capacity SPAs. Furthermore, any such significant impediment to our customers’ ability or willingness to deliver LNG from the United States generally, or from our projects specifically, could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Cyclical or other changes in the demand for and price of LNG and natural gas may adversely affect our business and the performance of our customers and could have a material adverse effect on our business, contracts, financial condition, operating results, cash flows, liquidity and prospects and the price of our Class A common stock.

Our LNG business and the development of domestic LNG facilities and projects generally is based on assumptions about the future availability and price of natural gas and LNG, and the prospects for international natural gas and LNG markets. In particular, changes in the price of natural gas that is supplied to our projects or any other natural gas liquefaction and export facility we may decide to develop in the future could affect the demand for, and price of, the LNG that our projects are expected to produce. Changes in the price of natural gas could also affect the competitiveness of LNG as a source of energy, which could adversely affect our customers or the demand for, and price of, LNG. Any of these factors could, in turn, affect the viability of natural gas liquefaction and export facilities such as those we are proposing to construct, and could require us to re-evaluate the viability of any of our planned projects and result in us postponing or abandoning our current plans for development of our projects. Natural gas and LNG prices have been, and are likely to continue to be, volatile and subject to wide fluctuations in response to one or more of the following factors:

 

   

competitive liquefaction capacity in North America;

 

   

insufficient or oversupply of natural gas liquefaction or receiving capacity worldwide;

 

   

insufficient LNG tanker capacity;

 

   

weather conditions, including temperature volatility resulting from changes in climate, and severe weather events may lead to unexpected distortion in the balance of international LNG supply and demand;

 

   

reduced demand and lower prices for natural gas;

 

60


Table of Contents
   

the extent of domestic production and importation of natural gas in relevant markets;

 

   

increased natural gas production deliverable by pipelines, which could suppress demand for LNG;

 

   

decreased oil and natural gas exploration activities, which may decrease the production of natural gas, including as a result of any potential ban on production of natural gas through hydraulic fracturing;

 

   

cost improvements that allow competitors to provide natural gas liquefaction capabilities at reduced prices;

 

   

changes in supplies of, and prices for, alternative energy sources such as coal, oil, nuclear, hydroelectric, wind and solar energy, which may reduce the demand for natural gas;

 

   

changes in regulatory, tax, environmental or other governmental policies regarding imported or exported LNG, natural gas or alternative energy sources, which may reduce the demand for imported or exported LNG and/or natural gas;

 

   

political conditions in natural gas producing regions, including geopolitical events such as the Russia-Ukraine conflict and the conflicts occurring in the Middle East;

 

   

sudden decreases in demand for LNG as a result of natural disasters or public health crises, including the occurrence of a pandemic, and other catastrophic events;

 

   

adverse relative demand for LNG compared to other markets, which may decrease LNG exports from North America; and

 

   

cyclical trends in general business and economic conditions that cause changes in the demand for natural gas.

For example, significant price fluctuations for natural gas could materially affect the value of our inventory, as well as the linefill and tank bottoms that we account for as non-current assets. We may be forced to delay some of our capital projects and our customers, who may be in financial distress, may slow down decision-making, delay planned projects or seek to renegotiate or terminate agreements with us. To the extent any of our counterparties is successful in any such renegotiation or termination, we may not be able to obtain new contract terms that are favorable to us or to replace contracts that are terminated. Counterparties may also be forced to file for bankruptcy protection, in which case our existing contracts with those counterparties may be rejected by the bankruptcy court.

Adverse trends or developments affecting any of these factors above could result in decreases in the price of LNG and/or natural gas, which could adversely affect the LNG business of our customers and the viability of our projects, and could also adversely affect the demand for, and price of, LNG, any of which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

There may be shortages of LNG tankers worldwide, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

The construction and delivery of LNG tankers require significant capital and long construction lead times, and the availability of the tankers (including the tankers that we have contracted to acquire) could be delayed to the detriment of our LNG business and our customers, and therefore our business, because of:

 

   

an inadequate number of shipyards constructing LNG tankers and a backlog of orders at these shipyards;

 

   

political or economic disturbances in the countries where the vessels are being constructed;

 

   

acts of war or piracy;

 

61


Table of Contents
   

changes in governmental regulations or maritime self-regulatory organizations;

 

   

work stoppages or other labor disturbances at the shipyards;

 

   

bankruptcy or other financial crisis of shipbuilders or shipowners;

 

   

quality or engineering problems;

 

   

disruptions to maritime transportation routes;

 

   

weather interference or a catastrophic event, such as a major earthquake, tsunami or fire; and

 

   

shortages of or delays in the receipt of necessary construction materials.

Delays in the construction and delivery of LNG tankers or other shortages in LNG tankers could result in decreases in the demand for LNG, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Technological innovation may render our anticipated competitive advantage or our processes obsolete.

Our success will depend on our ability to create and maintain a competitive position in the natural gas liquefaction industry. In particular, we are constructing our projects using technologies that we believe provide us with certain advantages (such as the mid-scale natural gas liquefaction trains to be supplied by Baker Hughes). However, we do not have any exclusive rights to any of the technologies that we will be utilizing, and our competitors may be planning to use similar or superior technologies.

In addition, the technologies that we are using or anticipate using in our projects may be rendered obsolete or uneconomical by technological advances, more efficient and cost-effective processes or entirely different approaches developed by one or more of our competitors or others. Our existing contractual arrangements with Baker Hughes would restrict our ability to utilize any such technological advances in our projects. Moreover, any changes to the design of our projects to incorporate any such technological advances could have a negative impact on the applications we have submitted to FERC with respect to those projects. As a result, we may not be able to take advantage of any such technological advances, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Risks Relating to Our Indebtedness and Financing

Our subsidiaries have incurred a significant amount of debt and issued a significant amount of preferred equity, which could adversely affect our financial condition.

As of September 30, 2024, our subsidiaries had approximately $27.2 billion in outstanding debt, which consisted of $11.0 billion of debt incurred by VGLNG and approximately $16.2 billion in project-level debt financing. In addition, our project-level equity investment subsidiaries for the Calcasieu Project, Calcasieu Holdings and Calcasieu Funding, have issued preferred units for total gross proceeds of $1.3 billion, with an aggregate liquidation preference of approximately $2.1 billion outstanding as of September 30, 2024, some of which require us to make preferential cash distributions to the holders under certain circumstances. VGLNG also issued 9.00% Series A Fixed-Rate Reset Cumulative Redeemable Perpetual Preferred Stock, with a $1,000 liquidation preference per share, or the VGLNG Series A Preferred Shares, which are entitled to preferential cash distributions, with an aggregate liquidation preference of $3.0 billion outstanding as of September 30, 2024. See “Description of Material Financing.” As of September 30, 2024, our subsidiaries had approximately $3.8 billion of additional borrowing capacity under our existing financing agreements. This substantial amount of indebtedness and preferred equity could have important consequences to us, including:

 

   

making it more difficult for us to satisfy our obligations with respect to our existing debt and our subsidiaries’ existing preferred equity;

 

62


Table of Contents
   

limiting our ability, or increasing the costs, to refinance our indebtedness;

 

   

limiting our ability to borrow additional amounts for working capital, capital expenditures, debt service requirements, execution of our business strategy or other purposes;

 

   

limiting our ability to use our cash and capital resources in other areas of our business because we must dedicate a substantial portion of these funds to service debt and preferred equity;

 

   

increasing our vulnerability to general adverse economic and industry conditions, including increases in interest rates, particularly given our substantial indebtedness that bears interest at variable rates;

 

   

limiting our ability to react to changing market conditions in our industry, to our customers’ businesses and to economic downturns;

 

   

limiting our ability to attract future customers for SPAs in connection with any expansion of our facilities compared with other companies that may have substantially less debt;

 

   

limiting our flexibility in planning for, or reacting to, changes in our business and future business opportunities;

 

   

limiting our ability to capitalize on business opportunities and to react to competitive pressures; and

 

   

resulting in a material adverse effect on our business, operating results and financial condition if we are unable to service our indebtedness or obtain additional capital, as needed.

Under the terms of certain agreements governing our indebtedness, we are permitted to incur additional indebtedness, which could further accentuate these risks.

Servicing our indebtedness and preferred equity will require a significant amount of cash and we may not have sufficient cash, operating cash flows and capital resources to service our existing and future indebtedness and preferred equity.

We may be required to use a substantial portion of our cash and capital resources to pay interest and principal on our indebtedness, as well as cash distributions or other required payments on preferred equity of our subsidiaries. Such payments may reduce the funds available to us to construct and complete the Calcasieu Project, the Plaquemines Project, the CP2 Project, the CP3 Project, the Delta Project or any other natural gas liquefaction and export facility we may develop, to acquire our LNG tankers, and for working capital, capital expenditures, and other corporate purposes, and limit our ability to obtain additional financing. This may in turn limit our ability to implement our business strategy, heighten our vulnerability to downturns in our business, the industry or in the general economy, and limit our flexibility in planning for, or reacting to, changes in our business and the industry.

We may not have sufficient cash, operating cash flows and capital resources to service our existing and future indebtedness and preferred equity. To date, we do not have any material sales, operating cash flow or operating history, other than the short-term sales of LNG commissioning cargos from the Calcasieu Project prior to commencing commercial operations, and we cannot assure you when we will begin to generate any operating cash flow from commercial operations. Our ability to service our debt and preferred equity will depend upon, among other things, our future financial and operating performance, which will be affected by prevailing economic conditions and financial, business, political, regulatory and other factors, some of which are beyond our control. We also cannot assure you that our business will generate sufficient cash flow from operations or that future financing will be available to us in amounts sufficient to enable us to make required and timely payments on our indebtedness or preferred equity, or to fund our operations.

If we face such liquidity problems, we could be forced to reduce or delay investments and capital expenditures or to dispose of material assets or operations, seek additional debt or equity capital or restructure or refinance our indebtedness or preferred equity. We may not be able to effect any such alternative measures, if

 

63


Table of Contents

necessary, on commercially reasonable terms or at all and, even if successful, those alternative actions may not allow us to make required payments on our indebtedness or preferred equity. In addition, certain agreements governing our existing indebtedness and preferred equity and the terms of such future agreements or preferred equity may also restrict our ability to raise debt or equity capital to be used to repay our existing indebtedness when it becomes due. We may not be able to consummate those dispositions or to obtain proceeds in an amount sufficient to make required payments on our indebtedness or preferred equity when due. If our cash, operating cash flows and capital resources are insufficient to fund those obligations, it could result in an event of default under such indebtedness, which, if not cured or waived, could result in the acceleration of all or a portion of our debt. As a result, our debtholders would be entitled to proceed to foreclose against all collateral that secures such debt, representing substantially all assets of the relevant project. In addition, if the distributions on preferred units issued by Calcasieu Funding are made in the form of an increase in the Funding Face Value (as described in “Description of Material Financing—Project Equity Financing—Calcasieu Pass Funding, LLC Preferred Units”) instead of in cash for six consecutive calendar quarters with the first full quarter following the commencement of commercial operations of the Calcasieu Project, certain investors may exercise step-in rights to control, directly or indirectly, certain of our subsidiaries and the Calcasieu Project.

As a holding company, the Company depends on the ability of its subsidiaries to transfer funds to it to meet its obligations.

The Company is a holding company for all of our operations and is a legal entity separate from its subsidiaries. As a result, the Company is dependent on the ability of its subsidiaries to make loans, pay dividends and make other payments to generate the funds necessary for the Company to meet its financial obligations and to pay dividends to stockholders, if any. The inability to receive dividends from its subsidiaries could have a material adverse effect on our business, financial condition, cash flows and results of operations, and the price of our Class A common stock.

The subsidiaries of the Company have no obligation to pay amounts due on any liabilities of the Company or to make funds available to the Company for such payments. The ability of our subsidiaries to pay dividends or other distributions to the Company in the future will depend, among other things, on their earnings, tax considerations and covenants contained in any financing or other agreements, such as the covenants governing our subsidiaries’ current indebtedness and preferred equity. In particular, our subsidiaries may incur additional indebtedness or issue additional preferred equity that may restrict or prohibit the making of distributions, the paying of dividends or the making of loans by such subsidiaries to the Company. See “—Certain of our debt agreements impose significant operating and financial restrictions on our subsidiaries, and the preferred equity of our subsidiaries also gives the holders certain consent rights, all of which may prevent us from capitalizing on business opportunities or paying dividends to the Company.” In addition, such payments may be limited as a result of claims against the Company’s subsidiaries by their creditors, including suppliers, vendors, lessors and employees.

If the ability of the Company’s subsidiaries to pay dividends or make other distributions or payments to the Company is materially restricted by cash needs, bankruptcy or insolvency, or is limited due to operating results or other factors, we may be required to raise cash through the incurrence of debt, the issuance of equity or the sale of assets. However, there is no assurance that we would be able to raise sufficient cash by these means. This could have an adverse effect on the Company’s ability to pay its obligations or pay dividends, if any, which could have a material adverse effect on our business, financial condition, cash flows and results of operations, and the price of our Class A common stock.

 

64


Table of Contents

Certain of our debt agreements impose significant operating and financial restrictions on our subsidiaries, and the preferred equity of our subsidiaries also gives the holders certain consent rights, all of which may prevent us from capitalizing on business opportunities or paying dividends to the Company.

The Calcasieu Pass Credit Facilities, the Plaquemines Credit Facilities and the indentures governing the VGCP Senior Secured Notes contain various covenants restricting the ability of certain of our subsidiaries to, among other things:

 

   

incur or guarantee additional debt or issue disqualified stock or preferred stock;

 

   

pay dividends (including to the Company) and make other distributions on, or redeem or repurchase, capital stock;

 

   

make certain investments;

 

   

incur certain liens;

 

   

enter into transactions with affiliates;

 

   

merge or consolidate;

 

   

enter into agreements that restrict the ability of restricted subsidiaries to make dividends or other payments to the issuers;

 

   

designate restricted subsidiaries as unrestricted subsidiaries; and

 

   

transfer or sell assets.

In addition, the credit agreement governing the Calcasieu Pass Credit Facilities requires VGCP to maintain a historical debt service coverage ratio of 1.15:1 for the 12-month period ending as of the end of any fiscal quarter. Analogous requirements apply to VGPL under the Plaquemines Credit Facilities when certain milestones are met.

The holders of preferred units of Calcasieu Holdings (or Class B common units after they are converted according to their terms) have the right to select and appoint one manager to the board of managers of Calcasieu Holdings, and such manager’s consent is required, among others, prior to:

 

   

amending key project contracts;

 

   

incurring any additional indebtedness in excess of $75.0 million, subject to certain exceptions; and

 

   

issuing or redeeming equity under certain circumstances.

In addition, other than Calcasieu Holdings contributing capital in exchange for issuance of common units in Calcasieu Funding, Calcasieu Funding may not issue additional units without a majority approval of holders of its preferred units.

Moreover, the indentures governing the VGLNG Senior Secured Notes contain various covenants restricting the ability of certain of our subsidiaries to, among other things:

 

   

incur or guarantee additional indebtedness or issue disqualified stock or certain preferred stock;

 

   

pay dividends and make other distributions or repurchase stock;

 

   

create or incur certain liens; and

 

   

merge, consolidate or transfer or sell all or substantially all of their assets.

Our failure to comply with the restrictive covenants described above as well as other terms of our other indebtedness and/or the terms of any future indebtedness from time to time could result in an event of default,

 

65


Table of Contents

which, if not cured or waived, could result in our being required to repay these borrowings before their due date. If we are forced to refinance these borrowings on less favorable terms or are unable to refinance these borrowings, there could be a material adverse effect on our business, financial condition and results of operations.

Additionally, if VGLNG does not pay semi-annual dividends on the VGLNG Series A Preferred Shares, certain terms of the VGLNG Series A Preferred Shares restrict VGLNG’s ability to pay dividends, repurchase its common stock, or issue certain types of securities. Furthermore, when any dividends on any VGLNG Series A Preferred Shares are in arrears for three or more consecutive semi-annual dividend periods, VGLNG is required to increase the number of members of its board of directors by two, until such time as all accrued dividends for all past dividend periods have been fully paid.

As a result of these restrictions, we will be limited as to how we conduct our business and we may be unable to raise additional debt or equity financing to compete effectively, distribute cash from our subsidiaries to the Company, or take advantage of new business opportunities. The terms of any future indebtedness we may incur or equity financing we may raise could include more restrictive covenants. We cannot assure you that we will be able to maintain compliance with these covenants in the future and, if we fail to do so, that we will be able to obtain waivers from the relevant lenders or holders and/or amend these covenants.

Our common equity interest in the Calcasieu Project will be diluted if we are unable to, or elect not to, pay certain distributions on the Holdings Preferred Units in cash.

As of September 30, 2024, a third-party investor currently holds 100% of the preferred units, or Holdings Preferred Units, of Calcasieu Holdings, which is an indirect parent entity of the Calcasieu Project. We have the option to pay the distributions on the Holdings Preferred Units either in kind in the form of issuing additional Holdings Preferred Units, or Holdings PIK Units, or in cash. See “Description of Material Financing—Project Equity Financing—Calcasieu Pass Holdings, LLC Preferred Units.” Upon COD at the Calcasieu Project, Holdings Preferred Units, including any Holdings PIK Units outstanding, will automatically convert into Class B common units of Calcasieu Holdings, or Class B Common Units. Assuming that we service all future distributions on the Holdings Preferred Units until the commencement of COD in cash, we expect the Holdings Preferred Units to automatically convert into a number of Class B Common Units, equal to approximately 23% of the total outstanding common units of Calcasieu Holdings, or Holdings Common Units, reducing our common equity interest in the Calcasieu Project to approximately 77%. However, if we are unable to, or elect not to, make payments on the Holdings PIK Units in cash, our common equity interest in the Calcasieu Project could be further diluted. While we expect to continue making distributions on the Holdings Preferred Units in cash, this is based on certain assumptions which could be affected by a number of factors beyond our control. In addition, we may enter into similar equity financing arrangements in the future with respect to our other projects. Greater dilution of our common equity interest in the Calcasieu Project or any other project would decrease our control over the Calcasieu Project (or such other project) and the amount of cash distributions that we receive from the Calcasieu Project (or such other project), which may have a material adverse effect on our business, financial condition, cash flows and results of operations, and the price of our Class A common stock.

Increases in interest rates would increase the cost of servicing our debt and could reduce our profitability.

The debt outstanding under the Calcasieu Pass Credit Facilities and the Plaquemines Credit Facilities bears interest at variable rates. While a substantial portion of such debt has been hedged to a fixed rate with interest rate swaps, increases in interest rates would increase the cost of servicing our subsidiaries’ debt, even if the amount borrowed remains the same, and could materially reduce our consolidated profitability and cash flows. As a result of such increases in the cost of servicing our subsidiaries’ debt, our subsidiaries may be unable to make distributions to us, which would negatively impact the price of our Class A common stock.

The U.S. Federal Reserve Board significantly increased the federal funds rate in 2022 and 2023 and it could maintain rates at historically high levels to combat inflation in the United States for longer than expected, which

 

66


Table of Contents

has increased the borrowing costs on our variable rate debt and may keep the cost of any new debt we incur at such increased levels. Any federal funds rate increases could in turn make our financing activities more costly and limit our ability to refinance existing debt when it matures or pay higher interest rates upon refinancing and increase interest expense on refinanced indebtedness.

Despite the current level of indebtedness and preferred equity issued by our subsidiaries, we expect to incur significant additional debt, some or all of which may be secured, and equity financing to fund the development, construction and completion of our projects. This could further exacerbate the risks to our financial condition described above.

Although we are subject to certain limitations on additional indebtedness and equity financing pursuant to the terms of agreements governing our existing indebtedness and preferred equity, these restrictions are subject to a number of qualifications and exceptions, and additional indebtedness and/or preferred equity incurred in compliance with these restrictions could be substantial. We expect to incur significant additional debt and equity financing to fund the development, construction and completion of the CP2 Project, the CP3 Project, the Delta Project and any other natural gas liquefaction and export facilities, or other projects, that we may decide to develop in the future. As of September 30, 2024, our subsidiaries had approximately $3.8 billion of additional borrowing capacity in the form of available commitments, comprised of approximately $2.6 billion of construction term loans under the Plaquemines Credit Facilities, approximately $919 million of working capital loans under the Plaquemines Working Capital Facility (after giving effect to approximately $1.2 billion of letters of credit issued under the Plaquemines Working Capital Facility), and approximately $301 million of working capital loans under the Calcasieu Pass Credit Facilities (after giving effect to approximately $254 million letters of credit issued under the Calcasieu Pass Working Capital Facility), all of which would have been secured. To the extent we or any of our subsidiaries incurs or issues additional debt and/or preferred equity, as applicable, the risks described in the preceding risk factors would increase.

Upon the occurrence of an event of default under our existing and future indebtedness, our lenders and the holders of our debt securities could elect to accelerate all or a portion of our debt. A delay in COD of the Calcasieu Project or Phase 1 or 2 of the Plaquemines Project beyond a certain deadline could also result in an event of default under the Calcasieu Pass Credit Facilities or the Plaquemines Credit Facilities, respectively, and/or certain investors exercising step-in rights to control, directly or indirectly, certain of our subsidiaries and the Calcasieu Project.

If we are unable to fund our debt service obligations or comply with restrictive covenants under our existing or future indebtedness, it could result in an event of default under such indebtedness which, if not cured or waived, could result in the acceleration of some or all of our debt. If we are unable to repay those amounts, our lenders and the holders of our debt securities could proceed to foreclose against the collateral securing such indebtedness. Any such foreclosure could have a material adverse impact on our business, financial condition, cash flows and results of operations, and the price of our Class A common stock.

In particular, we granted certain of our lenders under the Calcasieu Pass Credit Facilities and holders of the VGCP Senior Secured Notes (i) a first-priority perfected security interest in substantially all of VGCP’s and TCP’s existing and after-acquired personal property, including, without limitation, proceeds, insurance policies, agreements, permits and bank accounts; (ii) a mortgage on all material leasehold and fee interests of VGCP, including, without limitation, the Calcasieu Project site; (iii) a first-priority perfected security interest in 100% of the equity interests in certain subsidiaries relating to the Calcasieu Project; and (iv) all proceeds of the foregoing as collateral. In addition, Calcasieu Pass Pledgor, LLC granted the lenders and holders of the VGCP Senior Secured Notes a first-priority perfected security interest in all of the equity interests in VGCP and TCP. We also granted certain of our lenders under the Plaquemines Credit Facilities (i) a first-priority perfected security interest in substantially all of Plaquemines’ and Gator Express’ existing and after-acquired personal property, including, without limitation, proceeds, insurance policies, agreements, permits and bank accounts; (ii) a mortgage on all material leasehold and fee interests of Plaquemines, including, without limitation, the Plaquemines Project site;

 

67


Table of Contents

(iii) 100% of the membership interests in Plaquemines and Gator Express; and (iv) all proceeds of the foregoing as collateral. As a result, the lenders under any such indebtedness could proceed to foreclose against such collateral securing the applicable indebtedness following an event of default, which would have a material adverse impact on our business, financial condition, cash flows and results of operations, and the price of our Class A common stock.

Furthermore, if the Calcasieu Project does not commence commercial operation by a specified date certain (currently June 1, 2025), an event of default under the Calcasieu Pass Credit Facilities will occur. See “Description of Material Financing—Project Debt Financing.” In addition, if the Calcasieu Project does not commence commercial operation by the date that is 45 days prior to the date certain under the Calcasieu Pass Credit Facilities, holders of preferred units or Class B units in Calcasieu Holdings, or the Investors, will have the right to appoint a majority of the board of managers of Calcasieu Holdings, or the Step-In Right. Because Calcasieu Holdings is the sole member of the entity that wholly owns the Calcasieu Project and the TransCameron Pipeline, the Step-In Right not only gives the Investors significant control over Calcasieu Holdings but also over the Calcasieu Project and the TransCameron Pipeline. The Investors’ interests may differ from our interests or those of our stockholders, and therefore the Investors may not always exercise the control in a way that benefits us or our stockholders, which may have a negative impact on our business, financial conditions and results of operations and the price of our Class A common stock. See “Description of Material Financing—Project Equity Financing—Calcasieu Pass Holdings, LLC Preferred Units—Step-In Right.”

Our use of hedging arrangements may adversely affect our future operating results or liquidity.

To help mitigate our exposure to fluctuations in the price, volume and timing risk associated with the purchase of natural gas, we may use futures, swaps and option contracts traded or cleared on the Intercontinental Exchange and the New York Mercantile Exchange, or the NYMEX, or over-the-counter options and swaps with other natural gas merchants and financial institutions. Any hedging arrangements would expose us to risk of financial loss in some circumstances, including when:

 

   

expected supply is less than the amount hedged;

 

   

the counterparty to the hedging contract defaults on its contractual obligations; or

 

   

there is a change in the expected differential between the underlying price in the hedging agreement and actual prices received.

The use of derivatives also may require the posting of cash collateral with counterparties, which can impact working capital when commodity prices change.

The regulatory and other provisions of the Dodd-Frank Act and the rules adopted thereunder and other non-U.S. regulations, including EMIR and REMIT, could adversely affect our ability to hedge risks associated with our business and our operating results and cash flows.

The provisions of the Dodd-Frank Act and the rules adopted and to be adopted by the CFTC, the SEC and other federal regulators establishing federal regulation of the OTC derivatives market, and entities like us that participate in that market, may adversely affect our ability to manage certain of our risks on a cost effective basis. Such laws and regulations may also adversely affect our ability to execute our strategies with respect to hedging our exposure to variability in expected future cash flows attributable to the future sale of our LNG inventory and to price risk attributable to future purchases of natural gas to be utilized as fuel to operate our LNG terminals and to secure natural gas feedstock for our liquefaction facilities.

CFTC position limits rules restrict the amounts of certain speculative futures contracts, as well as economically equivalent options, futures and swaps for or linked to certain physical commodities, including Henry Hub natural gas, that market participants may hold, subject to limited exemptions for certain bona fide

 

68


Table of Contents

hedging positions and other types of transactions. The application of these requirements affect the overall derivatives market, including the costs and availability of the types of swaps we use to hedge or mitigate our commercial risks.

Under the CEA and the rules adopted thereunder, certain swaps may be required to be cleared through a DCO. While the CFTC has designated certain interest rate swaps and index credit default swaps for mandatory clearing, it has not yet adopted rules designating any physical commodity swaps, for mandatory clearing or mandatory exchange trading. Further, we qualify for and rely on the end-user exception from the mandatory clearing and trade execution requirements for any swaps entered into to hedge our commercial risks. If we fail to qualify for that exception as to any swap we enter into and have to clear that swap through a DCO, we could be required to post margin (or post higher margin than if we entered into an uncleared OTC swap) with respect to such swap, our cost of entering into and maintaining such swap could increase, and we would not enjoy the same flexibility with the terms of the cleared swaps that we enjoy with the uncleared OTC swaps we enter into. Moreover, the application of the mandatory clearing and trade execution requirements to other market participants, such as our counterparties, may change the market cost and general availability in the market of swaps of the type we enter into to hedge our commercial risks and, thus, the cost and availability of the swaps that we use for hedging.

For uncleared swaps, the CFTC and federal banking regulators have adopted rules to require certain market participants to collect and post initial and/or variation margin with respect to uncleared swaps from their counterparties that are financial end users and certain registered swap dealers and major swap participants. Although we believe we will not be required to post margin with respect to any uncleared swaps we enter into in the future, were we required to post margin as to our uncleared swaps in the future, our cost of entering into and maintaining swaps would be increased. In addition, some of our counterparties are subject to the regulations imposing capital requirements on them, which may increase the cost to us of entering into swaps with them because, although not required to collect margin from us under the margin rules, our counterparties may contractually require us to post collateral with them in connection with such swaps in order to offset their increased capital costs or to reduce their capital costs to maintain those swaps on their balance sheets.

While we are directly subject to only limited regulatory requirements for our derivatives, the application of these requirements to other market participants, including our counterparties, may affect the overall swaps market, including the costs and availability of swaps we may use to hedge or mitigate our risks. If, as a result of the swaps regulatory regime discussed above, we were to reduce our use of swaps to hedge our risks, our operating results and cash flows may become more volatile and could be otherwise adversely affected.

The Federal Reserve Board also has proposed rules that would limit certain physical commodity activities of financial holding companies. Such rules, if adopted, may adversely affect our ability to execute our strategies by restricting our available counterparties for certain types of transactions, limiting our ability to obtain certain services, and reducing liquidity in physical and financial markets. It is uncertain at this time whether, when and in what form the Federal Reserve’s proposed rules regarding physical commodity activities of financial holding companies may become final and effective.

European and UK-specific regulations, including but not limited to EMIR, MiFID II, REMIT, MAR, FSMA and the RAO, govern our trading activities and our compliance with such laws may result in increased costs and risks to the business similar to the impacts stated above with respect to the Dodd-Frank Act. The increased costs may also have an adverse impact on our business, contracts, financial condition, operating results, cash flow, liquidity and prospects. Further, any violation of the foregoing laws and regulations could result in investigations, and possible fines and penalties, and in some scenarios, criminal offenses.

Further, the potential for divergence between the UK and EU financial regulatory regimes following the UK’s withdrawal from the EU, has created uncertainty among market participants and may result in additional regulatory risks and compliance costs. While it is expected that the UK will maintain regulatory standards similar

 

69


Table of Contents

to those in the EU, technical differences have emerged recently and it is likely that this trend will continue to increase over time.

We expect that our hedging activities will remain subject to significant and developing regulations and regulatory oversight, and the ultimate effect on our business of any future changes to this regulatory regime remains uncertain.

Risks Relating to Regulation and Litigation

We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.

The design, construction and operation of the facilities constituting our projects, as well as the export of LNG and the transportation of natural gas, are highly regulated activities. Certain of our development projects remain subject to the application for and/or receipt of several material federal, state and local governmental and regulatory approvals and permits, as described further under “Business—Governmental Regulation.” Approvals of FERC and DOE under Sections 3 and 7 of the Natural Gas Act, or the NGA, as well as several other material governmental and regulatory approvals and permits, including under the Clean Air Act, or the CAA, and the Clean Water Act, or the CWA, are required in order to construct and operate an LNG facility and a natural gas pipeline, and to export the LNG produced at our projects. See also “Business—Environmental Regulation.” Our projects that have obtained needed approvals and permits remain subject to extensive regulation.

The authorizations obtained from FERC, DOE and other federal and state regulatory agencies also contain ongoing conditions, and such agencies may impose additional approval and permit requirements. DOE has stated that it has authority to amend, modify, or revoke existing LNG export authorizations issued pursuant to Section 3 of the NGA if necessary or appropriate to protect the public interest. In addition, the DOE may suspend or revoke our export authorizations if we, our customers, and/or their downstream customers, do not comply with the terms and conditions of the authorizations or if the DOE later determines that LNG exports are contrary to the public interest.

While we have received the applicable approvals from the Office of Fossil Energy and Carbon Management of the DOE authorizing the export of domestically produced LNG for the nameplate capacity as well as excess capacity up to the current permitted liquefaction capacity for the Calcasieu Project and the Plaquemines Project, our requests to increase the authorized export volumes from both projects to reflect an increased peak output have been granted only with respect to exports to FTA Nations while the requests with respect to Non-FTA Nations remain pending. Similarly, DOE has authorized LNG exports from the CP2 Project only to FTA Nations while our non-FTA application for that project remains pending. We have not yet made filings to the DOE regarding the export of any natural gas from the CP3 Project or the Delta Project. Moreover, we have not made any filings with DOE with respect to any of the potential bolt-on expansion opportunities at any of our projects.

In January 2024, the Biden administration announced a temporary pause on new authorizations of natural gas exports to non-FTA Nations while the DOE conducts studies to update its analyses regarding whether the exports are “not inconsistent with the public interest” to consider the latest available information regarding macro-economic impacts, domestic energy prices, potential greenhouse gas, climate or other environmental effects, and national security implications. On July 1, 2024, a Federal District Judge in Louisiana granted a motion for preliminary injunction by numerous states, holding the DOE pause appears to be unlawful and staying the pause in its entirety. Although the DOE’s pause has been stayed, the DOE has appealed the decision and has not acted on various pending export authorizations. The DOE did issue a non-FTA export authorization for one project on August 31, 2024 (NFE Altamira FLNG, a 2.8 mtpa project) but limited its term to 5-years, ruling that a more complete record is needed to evaluate a longer term.

On December 17, 2024, DOE publicly released a multi-volume study of its views of the potential effects of U.S. LNG exports on the domestic economy; U.S. households and consumers; communities that live near

 

70


Table of Contents

locations where natural gas is produced or exported; domestic and international energy security, including effects of U.S. trading partners; and the environment and climate. DOE stated that it intends to use this study to inform its public interest review of and future decisions regarding exports to non-FTA nations. The study is subject to a sixty-day public comment period and the finalization of the study and any application of it in future decision-making will be determined by the new presidential administration. Although President-elect Trump opposed the DOE pause on export authorizations and advocated prompt issuance of new authorizations in the course of his presidential campaign, we expect that most DOE long-term, non-FTA authorizations will be delayed at least until the new administration takes office and potentially thereafter. While the incoming Trump administration is widely expected to support LNG exports, there can be no assurance as to its views of the recently released DOE study or its future policies, or the impact of those policies on our existing and future projects, including our related contracts. See “—Risks Relating to our Business—Our customers or we may terminate our SPAs if certain conditions are not met or for other reasons.”

While FERC has authorized the siting, construction and operation of the Calcasieu Project and the Plaquemines Project, as well as of the related pipelines under Sections 3 and 7 of the NGA, additional authorizations from the Commission and/or staff of FERC, as applicable, to proceed with the construction of facilities for the Plaquemines Project and to complete commissioning and place facilities into commercial service, are required as part of FERC’s ongoing regulation of our projects.

The FERC issued its order authorizing the CP2 Project in June 2024. In July 2024, a group of opponents composed mostly of environmental groups filed a request for rehearing of the FERC authorization, raising a number of challenges to the FERC authorization. In a notice issued on August 29, 2024, FERC denied rehearing by operation of law. Project opponents consisting of numerous environmentalist organizations and certain individuals filed petitions for review of FERC’s authorization order with the US Court of Appeals for the D.C. Circuit on September 4, 2024. FERC denied a motion for stay of its authorization order on October 1, 2024. The D.C. Circuit denied a similar request for stay filed by project opponents on November 8, 2024, and established a schedule providing for briefing through April 2025.

On November 27, 2024, FERC issued an order on rehearing that generally rejected the arguments opposing the CP2 Project and noted that it remains confident in the authorization order, but decided to partially “set aside” its prior analysis of the cumulative air impacts of emissions of nitrogen dioxide (NO2) and particulate matter less than 2.5 micrometers (PM2.5) and to prepare a supplemental Environmental Impact Statement concerning that topic and to address it along with certain other air quality issues in a future order that FERC anticipates issuing no later than July 24, 2025. FERC also announced that, due to its initiation of supplemental environmental review, it will not issue authorizations to proceed with construction until FERC issues a further merits order. In response to FERC’s order on rehearing, the D.C. Circuit on December 13, 2024, granted an unopposed motion by FERC to hold the appeal in abeyance, which will delay briefing of the D.C. Circuit appeal. In addition to the supplemental environmental review and the appeal, construction of the CP2 Project will be subject to ongoing oversight and needed additional authorizations by FERC in accordance with the terms and conditions of the CP2 Project FERC order. While we have already begun to submit implementation plans for that purpose, FERC has not yet authorized any on-site construction as of the date of this prospectus. There can be no assurance as to the timing of the supplemental environmental review, FERC’s further merits order, or authorizations from FERC for any on-site construction, and as a result there can be no assurance as to when we will be able to commence on-site construction for the CP2 Project.

We cannot predict whether our applications, approvals or permits will attract significant opposition or whether the permitting process will be lengthened due to complexities and appeals, including uncertainty and delays in the timetable on which the DOE will issue the non-FTA export authorization for the CP2 Project and for increases in the peak output for the Calcasieu and Plaquemines Projects, as well as for the FERC and DOE to act on future applications for the CP3 Project, the Delta Project or any potential bolt-on expansion opportunities in our projects in the future, litigation by environmental groups and other advocates concerned about the impact of our projects on climate change and pollution as well as resistance by local communities due to environmental,

 

71


Table of Contents

health and safety concerns. A number of environmental groups have opposed the regulatory approvals necessary for the CP2 Project, as well as the increase in the permitted capacity for the Plaquemines Project. For example, in a December 11, 2023 letter to the DOE, a coalition of more than 200 environmental groups called on the DOE to deny the export license for Non-FTA Nations for the CP2 Project on the basis that it is not in the public interest due to the alleged impact of LNG exports on the climate and environmental justice, as well as domestic energy prices, and DOE subsequently issued its “pause” on new authorizations described above. In addition, the Sierra Club and similar organizations have appealed the recent FERC approval of the CP2 Project, and they have in some instances successfully challenged FERC orders authorizing other LNG and natural gas pipeline projects. As another instance of appeal, in November 2022, three environmental groups filed suit in a Louisiana court challenging the state’s decision not to require a coastal use permit for the Plaquemines Project, which was subsequently dismissed on venue grounds.

Opposition to our projects from environmental groups and other advocates may increase and strengthen over time. As noted above, opponents of the CP2 Project have both sought rehearing of and appealed the FERC authorization of the project. Those entities likely will continue to oppose the CP2 Project and its regulatory authorizations, including its export authorization for Non-FTA Nations. Any appeal of or litigation relating to our permits or approvals may delay the development of our natural gas liquefaction and export facilities. There can be no assurance that any opposition, appeals or other litigation, which may be entered after the granting of authorization by FERC (as in the existing appeal) or DOE (once it issues the non-FTA authorization), will not be successful or not delay our ability to develop the CP2 Project, the CP3 Project or the Delta Project, any bolt-on expansion to any of our projects we pursue in the future, or any other project we may seek to develop.

We do not know whether or when any of the approvals or permits we require can be obtained, whether any existing or potential future interventions or other actions by third parties will interfere with our ability to obtain and maintain such approvals or permits, whether any such approvals and permits may be revoked or altered in the future, or whether we will be able to comply with the conditions or requirements that such approvals or permits might impose. In addition, requests by regulators for additional information or additional regulatory submissions may delay the regulatory approval process and may also lead to changes in our project design. There is no assurance that we will obtain and maintain these governmental approvals and permits, or that we will be able to obtain them on a timely basis.

The denial of an application, approval or permit essential to a project or bolt-on expansion opportunity or the imposition of impractical conditions would impair our ability to develop a project or bolt-on expansion opportunity. Similarly, a delay in the review and permitting process for our projects or bolt-on expansion opportunities could impair or delay our ability to develop the relevant project or bolt-on expansion opportunity or increase the cost so substantially that the relevant project or bolt-on expansion opportunity is no longer financially attractive to us. In particular, certain of the foregoing approvals and permits must be obtained before construction of the CP2 Project, the CP3 Project and the Delta Project can begin, before the Plaquemines Project is completed, before commercial operations of the Calcasieu Project can commence, and before we can pursue any potential bolt-on expansion opportunities at our projects. If we are unable to obtain and maintain the necessary approvals and permits or satisfy additional permit requirements imposed on us, we may not be able to complete our projects on schedule or operate them and provide services to our customers under the SPAs and, consequently, a failure to obtain and maintain any of these permits, approvals or authorizations could have a material adverse effect on our business, financial condition, operating results, liquidity, prospects and the price of our Class A common stock.

In the future, additional regulatory approvals may be required or significant costs may be incurred due to delays caused by the opposition, changes in laws and regulations or for other reasons. In addition, zoning, environmental, health and safety laws and regulations are subject to periodic amendment or promulgation and may become more stringent over time. Accordingly, we cannot assure that such laws or regulations will not be changed or reinterpreted or that new laws or regulations will not be adopted. The costs of complying with future laws and regulations may require us to incur materially higher costs.

 

72


Table of Contents

There can be no assurance that our existing or future regulatory approvals will not be subject to other legal challenges, or that such approvals will not be re-examined vacated, withdrawn, overturned, altered or otherwise modified in a manner adverse to the development, construction or operation of one or more of our projects or to our business more generally. If we are required to modify our activities as a result of any changes to our existing regulatory approvals, the impact could increase our project costs, delay our project timelines, affect our ability to complete our planned projects, or result in claims from third parties if we are unable to meet our commitments under our pre-existing commercial agreements, all of which could have a material adverse effect on our business. As of the date of this prospectus, we have not yet submitted a formal FERC application for the CP3 Project or the Delta Project. We have not made any filings with FERC with respect to any of the potential bolt-on expansion opportunities at any of our projects.

Our interstate natural gas pipelines and their FERC gas tariffs are subject to FERC regulation.

Our natural gas pipelines providing interstate transportation are subject to regulation by FERC under the NGA and under the Natural Gas Policy Act of 1978, or the NGPA. FERC regulates the transportation of natural gas in interstate commerce, including the construction and operation of pipelines, the rates, terms and conditions of service and abandonment of facilities. Under the NGA, the rates charged by interstate natural gas pipelines must be just and reasonable, and we are prohibited from unduly preferring or unreasonably discriminating against any person with respect to pipeline rates or terms and conditions of service. If our interstate natural gas pipelines fail to comply with all applicable statutes, rules, regulations and orders, they could be subject to substantial penalties and fines. See “—Existing and future environmental and similar laws and governmental regulations could result in increased compliance costs or additional operating and/or construction costs and restrictions.”

As our interstate natural gas pipelines are subject to FERC regulations, we must file FERC gas tariffs, as well as any subsequent changes to the filed FERC gas tariffs or agreements related to the pipelines from time to time, with FERC for approval for each of our pipelines. For more information on these tariffs, see “Business—Governmental Regulation.” The construction and operation of any new, modified, or expanded facilities on our pipelines may also require FERC authorization. There can be no assurance that FERC will accept such filings on anticipated terms and timelines, or at all. See “—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

Should we, or any of our applicable subsidiaries that own a FERC-jurisdictional pipeline fail to comply with all applicable FERC-administered statutes, rules, regulations and orders, we or such subsidiary could be subject to substantial penalties and fines. Under the Energy Policy Act of 2005, or EPAct, FERC has civil penalty authority under the NGA and the NGPA to impose penalties for violations of currently up to approximately $1.55 million currently (with future changes indexed to inflation) per day for each violation.

Pipeline safety integrity programs and repairs may impose significant costs and liabilities on us.

The Pipeline and Hazardous Materials Safety Administration, or PHMSA, has exclusive authority to establish and enforce safety regulations for onshore LNG facilities and pipelines transporting hazardous materials such as natural gas. PHMSA periodically inspects LNG facilities and operators to enforce compliance with the applicable safety regulations. During the inspections, PHMSA reviews operator records to determine if facility equipment has been properly maintained and if the operator has developed and follows operation, maintenance, security, and emergency procedures that ensure the continued safe operation of the facility. Compliance with PHMSA requirements, which may change over time, can impose additional costs or liabilities on us or adversely affect our operations. PHMSA enforces violations it finds, which can include civil penalties or orders directing action. In addition, if PHMSA finds conditions that are hazardous, it can require the shut-down of the relevant facilities and expeditious corrections of the conditions through corrective action orders.

PHMSA also requires pipeline operators to develop integrity management programs to comprehensively evaluate certain areas along their pipelines and to take additional measures to protect pipeline segments located

 

73


Table of Contents

in “high consequence areas” where a leak or rupture could potentially do the most harm. As an operator, we are required to:

 

   

perform ongoing assessments of pipeline integrity;

 

   

identify and characterize applicable threats to pipeline segments that could impact a “high consequence area”;

 

   

improve data collection, integrate and analyze pipeline data;

 

   

repair and remediate the pipeline as necessary; and

 

   

implement preventative and mitigating actions.

We are required to maintain pipeline integrity testing programs that are intended to assess pipeline integrity. The costs of compliance with integrity management programs and other PHMSA requirements may be difficult to predict. Furthermore, these standards are subject to regular statutory and regulatory revision and generally have become more stringent over time, as PHMSA promulgates new or revised regulations and as Congress amends existing pipeline safety laws. If these standards become more stringent in the future, it could cause us, like other similarly situated pipeline operators, to incur increased costs for operating our pipelines, to incur increased costs for developing future projects, or to suffer potential adverse impacts to our operations. For instance, on May 4, 2023, PHMSA issued a proposed rulemaking implementing congressional mandates to reduce methane emissions from new and existing natural gas transmission, regulated gathering and distribution pipelines, natural gas storage, and LNG facilities. The proposed rule imposes enhanced leak survey and patrolling requirements, standards for leak detection programs, leak grading and repair criteria, repair timelines, requirements for mitigation of emissions from blowdowns, requirements for investigating failures, and criteria for the design, configuration and maintenance of pressure relief devices. As a result, operators of pipelines and facilities affected by the final rule, once promulgated, may be required to make operational changes or modifications at their facilities to meet standards beyond current requirements, which changes or modifications may result in additional capital costs, possible operational delays and increased costs of operation that, in some instances, may be significant.

Any repair, remediation or delayed remediation, preventative or mitigating actions may require significant capital and operating expenditures and may subject us to significant reputational or financial risk. Should we fail to comply with applicable statutes and the PHMSA rules and related regulations and orders, we could be subject to significant penalties and fines, which would have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Existing and future environmental and similar laws and governmental regulations could result in increased compliance costs or additional operating and/or construction costs and restrictions.

Our business is and will be subject to extensive federal, state and local laws and regulations that regulate and restrict, among other things, discharges to air, land and water, with particular respect to the protection of the environment and natural resources; the handling, storage and disposal of hazardous materials, hazardous waste, and petroleum products; and investigation and remediation associated with the release of hazardous substances. Many of these laws and regulations, such as the CAA, Oil Pollution Act, or OPA, CWA, Comprehensive Environmental Response, Compensation, and Liability Act, or CERCLA, and Resource Conservation and Recovery Act, or RCRA, and analogous state laws and regulations, restrict or prohibit the types, quantities and concentration of substances that can be released into the environment in connection with the construction and operation of our projects and any other natural gas liquefaction and export facility we may decide to develop in the future, and require us to maintain permits and provide governmental authorities with access to our facilities for inspection and to provide reports related to our compliance. In addition, certain laws and regulations authorize regulators having jurisdiction over the construction and operation of our projects and related pipelines,

 

74


Table of Contents

including FERC, PHMSA, EPA and the United States Coast Guard, to issue regulatory enforcement actions, which may restrict or limit operations or increase compliance or operating costs. Violation of these laws and regulations could lead to substantial liabilities, compliance orders, fines and penalties, operational or construction restrictions, difficulty obtaining and maintaining permits from regulatory agencies or capital expenditures and operational costs related to pollution control equipment that could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Federal and state laws impose liability, without regard to fault or the lawfulness of the original conduct, for the release of certain types or quantities of hazardous substances into the environment. As the owner and operator of the proposed liquefaction facilities, we could be liable for the costs of investigating and cleaning up hazardous substances released into the environment at or from our facilities and for resulting damage to natural resources, including as they relate to releases of hazardous substances that pre-date our possession and operation.

We have conducted Phase I environmental studies on all of our project sites, and from time to time we have encountered environmental conditions on certain sites that we may be required to monitor or address prior to making use of the relevant project site. In addition, future studies and analyses may reveal adverse environmental conditions on them of which we are not currently aware, and we may be required to investigate and remediate such conditions or make other changes to those sites. Any discovery of preexisting, or occurrence of new, environmental conditions that require remediation or other alterations to our current plans for our projects could delay or prevent the construction of that project, or require us to pay penalties or fines or otherwise incur significant losses and liabilities, any of which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

On December 15, 2009, the Environmental Protection Agency, or the EPA, published its findings that emissions of carbon dioxide, methane and other “greenhouse gases” present an endangerment to human health and the environment because emissions of such gases are, according to EPA, contributing to the warming of the Earth’s atmosphere and other climatic changes. Federal and state regulatory authorities have been pursuing a number of regulatory and policy initiatives to reduce greenhouse gas, or GHG, emissions in the United States from a variety of sources, but such initiatives can be controversial and subject to change depending on legal and political developments. For example, in October 2015, the U.S. promulgated the Clean Power Plan, designed to reduce GHG emissions from existing power plants in the United States, and a regulation establishing GHG performance standards for new, modified and reconstructed power plants. The U.S. Supreme Court stayed implementation of the Clean Power Plan soon after its enactment, and on June 30, 2022, the Court held that EPA does not have authority under the Clean Air Act to set emissions caps based on a “generation shifting” approach as set forth in the Clean Power Plan. On May 9, 2024, the EPA finalized a new rule regulating GHG emissions from the power sector that would phase in requirements for certain fossil fuel-fired power plants to implement GHG reduction methods, including, among other things, the installation of systems to capture and sequester their carbon emissions.

Our business and operations could be affected by climate-related regulations. In December 2023, EPA issued an estimate of the social cost of carbon, which is the cost of GHG emissions that federal agencies are to take into account in assessing the costs and benefits of regulatory actions, as being $190 per ton for the year 2020. While the full impact of this measure is difficult to predict, the inclusion of such costs has the potential to result in regulations that are more restrictive and costly for GHG emitters. On February 19, 2021 the Biden Administration formally rejoined the Paris Agreement and on April 22, 2021 during the Global Leaders Summit on Climate, announced a new target to achieve a 50-52% reduction from 2005 levels in economy-wide net GHG emissions by 2030. In December 2023 at the COP28 climate summit, representatives from nearly 200 nations, including the U.S., reached an agreement that calls on governments to transition away from fossil fuels in energy systems in order to achieve net zero by 2050, but noted that natural gas (including LNG) can play a role in cutting emissions. On December 2, 2023, EPA issued a final rule updating and broadening requirements for new,

 

75


Table of Contents

modified, and reconstructed oil and gas sources, including oil and gas wells, controllers, pumps, storage vessels, and compressor stations aimed at reducing methane and volatile organic compound emissions and directing states to develop plans largely paralleling these requirements for hundreds of thousands of existing oil and gas sources. The rule also includes a Super-Emitter Response Program, whereby qualified third parties may document super-emitter events and notify owners or operators of affected sites, requiring them to investigate and take measures to mitigate methane emissions. Additionally, in May 2023, PHMSA announced new proposed rules to strengthen and update leak detection and repair standards for gas pipelines aimed at reducing methane emissions from covered pipelines by up to 55% by 2030. Such rules may impact our operations as well as those of our upstream supply chain partners. The election of Donald Trump—who has generally expressed opposition to regulatory initiatives aimed at restricting oil and gas operations as well as stated his desire to once again exit the U.S. from the Paris Agreement—and the impact it will have on any of these initiatives cannot be predicted.

Section 60113 of the Inflation Reduction Act, which was signed into law on August 16, 2022, establishes a charge on excess methane emissions from various facilities operating in the oil and gas sector, including liquefied natural gas storage and liquefied natural gas import and export equipment, that report more than 25,000 metric tons of carbon dioxide equivalent emissions per year. For liquefied natural gas facilities, the excess emissions charge ($900 per ton for emissions reported in calendar year 2024, rising to $1,500 per ton for such emission beginning with calendar year 2026) is based on the reported tons of methane emissions that exceed 0.05 percent of the natural gas sent to sale from or through such facilities. We anticipate that our facilities will be subject to such excess emissions charge.

The United States Congress has also considered other legislation to restrict or regulate emissions of GHGs. While it remains unclear whether Congress will be able to agree on comprehensive climate legislation in the near future, energy legislation and other initiatives may seek to address GHG emissions issues or restrict oil and gas operations. In addition to the uncertainties in federal climate policy, we could still be subject to or impacted by international initiatives, state initiatives or by future federal regulatory initiatives, which could include direct GHG emissions regulations, a carbon emissions tax, or cap-and-trade programs. Such initiatives could affect the demand for or cost of natural gas, which we consume at our terminals, or could increase compliance costs for our operations.

Other federal and state initiatives, as well as initiatives in foreign jurisdictions where we intend to market our products, have been implemented, are being considered or may be considered in the future to address GHG emissions and other climate and environmental concerns. These may include, but are not limited to, treaty commitments, direct regulation, carbon emissions taxes, cap and trade programs or mandates to the power sector to incorporate certain percentages of renewable energy into their portfolio. For example, the EU has adopted a legally binding target of net zero GHG emissions by 2050. Additionally, in August 2024, an EU regulation went into effect that is aimed at reducing methane emissions associated with natural gas, oil and coal imports and imposes monitoring, reporting and verification standards on importers of fossil fuels into the EU with respect to the “life cycle” methane emissions associated with the products.

In addition, from time to time, proposals have been made to change the way FERC considers GHG emissions in reviewing applications under the National Environmental Policy Act, or NEPA, and the NGA. In February 2022, FERC released an interim policy statement for consideration of GHG emissions in natural gas infrastructure reviews, though it later converted it to a draft statement subject to further comment and it has not been finalized. In January 2023, the Council on Environmental Quality, or CEQ, issued interim guidance to assist agencies, including FERC, in analyzing GHG emissions and climate change effects under NEPA. Additionally, in September 2023, the White House directed agencies to consider the social cost of GHG emissions when conducting environmental reviews pursuant to NEPA. In May 2024, CEQ published its final “Phase 2” NEPA regulations which include specific direction to account for both climate change and environmental justice effects in NEPA reviews. Activism from environmental groups aimed at agency decision making, such as the December 2023 letter from the coalition of environmental groups urging the DOE to deny the export license for Non-FTA Nations for the CP2 Project, may lead FERC and other agencies to consider the indirect impacts of projects such

 

76


Table of Contents

as ours on upstream emissions of GHG or to quantify the economic effect of climate change impacts associated with GHG emissions of a project. In addition, regulatory initiatives have been proposed to require companies to publicly disclose information relating to the impacts of climate change and their direct, indirect and supply chain GHG emissions, such as the SEC rule on climate-related risks. Such initiatives could affect the demand for, or the availability or cost of, natural gas, which we consume at our terminals, or could increase compliance costs for our operations. The impact of the election of Donald Trump, who has expressed support for domestic oil and gas production, on these initiatives cannot be predicted.

GHG emissions (such as carbon dioxide and methane) that could be regulated include, among others, those associated with our power generation, liquefaction and transportation of natural gas, and consumers’ or customers’ use of our products. Many of these activities, such as consumers’ and customers’ use of our products, as well as actions taken by our competitors in response to such laws and regulations, are beyond our control. Attention to climate change risks has also resulted and may continue to result in private initiatives by certain members of the investment community as well as public interest groups aimed at discouraging the production, development and consumption of fossil fuels.

GHG emissions-related laws and related regulations, consumer and investor preferences with respect to fossil fuels and the effects of operating in a potentially carbon-constrained environment may result in substantially increased capital, compliance, operating and maintenance costs and could, among other things, reduce demand for LNG, make our products more expensive and adversely affect our sales volumes, revenues and margins.

The ultimate effect of international agreements and national, regional and state legislation and regulatory measures to limit GHG emissions on our financial performance, and the timing of these effects, will depend on numerous factors. Such factors include, among others, the sectors covered, the GHG emissions reductions required and the extent to which we are able to recover the costs incurred through the pricing of our products in the competitive marketplace. Further, the ultimate impact of GHG emissions-related agreements, legislation, regulations, or private initiatives on our financial performance is highly uncertain because the company is unable to predict with certainty, for a multitude of individual jurisdictions, the outcome of political decision-making processes and the variables and tradeoffs that inevitably occur in connection with such processes and the timing thereof.

Other future legislation and regulations, such as those relating to the transportation and security of LNG exported from our projects, could cause additional expenditures, restrictions and delays in our business and to our proposed construction, the extent of which cannot be predicted and which may require us to limit substantially, delay or cease operations in some circumstances. Revised, reinterpreted or additional laws and regulations that result in increased compliance costs or additional operating or construction costs and restrictions could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We are involved and may in the future become involved in disputes and legal proceedings.

We are involved in and may in the future become involved in disputes as well as legal proceedings with public authorities, shareholders, suppliers, contractors, customers and others. Given the nature of our business, such disputes and legal proceedings often involve highly complex legal and factual questions and determinations and, in some cases, introduce significant levels of exposure.

For example, we are currently involved in arbitration proceedings with certain of our customers under our post-COD SPAs related to the Calcasieu Project. See “—If we are unsuccessful in our current and any potential future arbitration proceedings with our customers, the amounts that we are required to pay may be substantial and certain of our post-COD SPAs may be terminated, which may lead to an acceleration of all our debt for the relevant project.”

 

77


Table of Contents

In addition, in 2024 certain of our former employees filed proceedings, including in Virginia federal court, seeking aggregate damages of approximately $214 million with respect to alleged breaches of certain stock option grant agreements and related matters. We disagree with the assertions in each of these proceedings and are defending ourselves and asserting counterclaims, where applicable. However, there can be no assurance that we will be successful in defending such claims.

Further, from time to time, we may be a party to various administrative, regulatory or other legal proceedings, and others may allege that we are in violation or in default under orders, statutes, rules or regulations relating to the environment, compliance plans imposed or agreed to by us, or permits issued by various local, state or federal agencies for the construction or operation of our natural gas liquefaction facilities. For instance, BP previously filed a complaint with FERC in December 2023, which was subsequently withdrawn in July 2024, alleging that the Calcasieu Project has actually been in-service since 2022 and is operating commercially, seeking to consolidate the complaint proceeding with the ongoing proceeding for the commissioning of the project. In addition, when we filed with FERC in February 2024 for an extension of time, if deemed necessary, of the condition in our February 2019 FERC authorization order requiring the Calcasieu Project’s “proposed liquefaction facilities” be placed in-service within five years of the order, our long-term customers filed numerous responsive pleadings, predominantly seeking access to information filed with FERC on a confidential basis and to intervene in the on-going commissioning process. We have responded to customer filings in the extension of time filing proceeding, which remains pending before FERC.

Assessment of potential outcomes and the potential damages and other losses we may incur arising out of any current or future disputes or legal proceedings is inherently difficult given, among other things, the complex nature of the facts and law involved. Although we may disagree with any assertions and claims made against us in any such disputes or legal proceedings, we may not be successful in defending against such claims. If legal proceedings are resolved against us or if we make out-of-court settlements, we may be obliged to make substantial payments to other parties. Even if we are ultimately successful in the legal proceedings, such proceedings may distract our management team and we may also face harm to our reputation from case-related publicity. Further, any such disputes or legal proceedings could result in substantial costs to us associated with defending such claims and distract management, and could also impact our ability to complete our projects and any natural gas liquefaction and export facility we may decide to develop in the future on their respective anticipated timelines and at their respective anticipated costs.

If we are unsuccessful in our current and any potential future arbitration proceedings with our customers, the amounts that we are required to pay may be substantial and certain of our post-COD SPAs may be terminated, which may lead to an acceleration of all our debt for the relevant project.

We are involved and may in the future become involved in disputes and arbitration proceedings with the customers under our SPAs. For example, in December 2022, a long-term customer of the Calcasieu Project submitted a request for arbitration to the International Chamber of Commerce, International Court of Arbitration, in accordance with the dispute resolution procedures of the post-COD SPA between us and that customer, asserting that we had failed to provide sufficient information or access to the Calcasieu Project and are delayed in achieving COD under the post-COD SPA. The remedies sought by the long-term customer are contract damages in excess of $1 billion (which is potentially subject to increase with the passage of time until COD occurs), rather than the termination of the post-COD SPA. The initial merits hearing for this arbitration proceeding occurred in September 2024.

In May 2023, two additional long-term customers of the Calcasieu Project submitted separate requests for arbitration to the London Court of International Arbitration and the International Chamber of Commerce, International Court of Arbitration, respectively, in accordance with the dispute resolution procedures of the relevant post-COD SPAs with such customers, asserting, among other claims, that we are delayed in achieving COD under the post-COD SPA. The remedies sought by such long-term customers are (a) orders requiring us to immediately notify the relevant long-term customer of the occurrence of COD of the Calcasieu Project or

 

78


Table of Contents

otherwise deliver LNG cargos to the relevant long-term customer at the contract price set forth in the applicable post-COD SPA; and (b) contract damages of approximately $1.5 billion and $1.7 billion (each of which is potentially subject to increase with the passage of time until COD occurs), respectively, rather than the termination of the relevant post-COD SPAs. The hearings for such two arbitration proceedings occurred in October 2024 and November 2024, respectively.

In August 2023, two additional long-term customers of the Calcasieu Project submitted separate requests for arbitration to the International Chamber of Commerce, International Court of Arbitration in accordance with the dispute resolution procedures of the relevant post-COD SPAs with such customers, asserting, among other claims, that we are delayed in achieving COD under the relevant post-COD SPA. The hearings for such two arbitration proceedings have been scheduled for June 2025 and July 2025, respectively. In December 2023, one additional long-term customer of the Calcasieu Project submitted a request for arbitration to the International Chamber of Commerce, International Court of Arbitration in accordance with the dispute resolution procedures of the post-COD SPA between us and that customer, asserting among other claims that we are delayed in achieving COD under the relevant post-COD SPA. The remedies sought by each of the second group of three long-term customers are (a) orders requiring us to immediately notify the relevant long-term customer of the occurrence of COD of the Calcasieu Project or otherwise deliver LNG cargos to the relevant long-term customer at the contract price set forth in the applicable post-COD SPA; and (b) contract damages in an amount to be determined in excess of $250 million (in the case of one such customer) or $400 million (in the case of two such customers), rather than the termination of the relevant post-COD SPAs.

Further, in March 2024, a short-term customer of the Calcasieu Project submitted a request for arbitration to the International Chamber of Commerce, International Court of Arbitration in accordance with the dispute resolution procedures of the post-COD SPA between us and that customer. Such customer has raised substantially the same assertions as the arbitration proceedings described above and is seeking contract damages of $200 million (which is potentially subject to increase with the passage of time until COD occurs), as well as an additional claim relating to an undelivered commissioning cargo. Additionally, all such customers who have asserted that we are delayed in achieving COD have also disputed that the delay to COD constitutes a force majeure event in the context of their arbitration proceedings. We disagree with the assertions in each of these requests for arbitration, and are defending ourselves in the arbitration proceedings in accordance with each underlying post-COD SPA. We also note that, while we believe that the foregoing assertions in each request for arbitration are unsubstantiated, we further believe that any award of contract damages would be subject to the relevant seller aggregate liability cap under the relevant post-COD SPA. However, there can be no assurance that we will be successful in defending such claims or establishing that any such claim is subject to the liability cap under the relevant post-COD SPA.

In addition, although none of the post-COD SPA customers who have commenced the arbitration proceedings described above has sought termination of the underlying post-COD SPA as a remedy in the relevant arbitration, two of those long-term post-COD SPA customers have notified the collateral agent for the Calcasieu Project’s project financing that a potential termination event under their long-term post-COD SPA has occurred or may occur, and that remedies could include termination of, or suspension under, the relevant long-term post-COD SPA.

If we are unsuccessful in defending ourselves against any of the claims mentioned above, the amounts we could be required to pay could be substantial, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, liquidity and prospects. Further, a termination of, or suspension under, any of the relevant long-term post-COD SPAs that are subject to these claims could, subject to our ability to replace such long-term post-COD SPAs, lead to an acceleration of our outstanding debt under the Calcasieu Project and foreclosure against all collateral that secures such debt, representing substantially all assets of the Calcasieu Project, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

 

79


Table of Contents

We have also notified all of our customers under the Calcasieu Foundation SPAs of the anticipated delay to COD, indicating that such delay is due to a force majeure event. As a result of such designation, the deadline for COD in such post-COD SPAs would be extended and such customers will not be entitled to terminate their respective post-COD SPAs as a result of failure to designate COD until June 2025. All of such customers have questioned (including, as applicable, in the post-COD SPA arbitration proceedings described above) whether the delay constitutes a force majeure event and they could assert that, notwithstanding our declaration of force majeure, they are entitled to terminate their post-COD SPAs. Discussions with such customers with respect to this force majeure event remain ongoing. Such customers may also seek contract damages, and several such customers have already sought contractual damages in connection with the alleged delay in achieving COD for the Calcasieu Project as described above. Any such claims could be substantial, and there can be no assurance that we will be successful in defending any such claims.

If any of our customers were to successfully terminate their post-COD SPAs with us for the Calcasieu Project, we would need to replace those customers and/or amend our existing post-COD SPAs, which could take time and there can be no assurance we would be able to enter into new post-COD SPAs on a timely basis and on comparable or better terms. See “—Risks Relating to Our Business—Our customers or we may terminate our SPAs if certain conditions are not met or for other reasons.” See also “—Risks Relating to Our Indebtedness and Financing—Upon the occurrence of an event of default under our existing and future indebtedness, our lenders and the holders of our debt securities could elect to accelerate all or a portion of our debt. A delay in COD of the Calcasieu Project or Phase 1 or 2 of the Plaquemines Project beyond a certain deadline could also result in an event of default under the Calcasieu Pass Credit Facilities or the Plaquemines Credit Facilities, respectively, and/or certain investors exercising step-in rights to control, directly or indirectly, certain of our subsidiaries and the Calcasieu Project.”

Risks Relating to Intellectual Property, Data Privacy and Cybersecurity

Hostile cyber intrusions, or other issues with our information technology, could severely impair our operations, lead to the disclosure of confidential information, damage our reputation and otherwise have a material adverse effect on our business.

Our projects and any other natural gas liquefaction and export facilities (including any expansion of existing facilities) we may decide to develop in the future include assets deemed by FERC to constitute critical energy infrastructure, the operation of which is dependent on our information technology, or IT, systems. The IT systems that run our natural gas liquefaction and export facilities are not completely isolated from external networks. A successful cyber-attack on the systems that will control our assets could severely disrupt business operations, preventing us from serving customers or collecting revenues, as well as expose us to other risks. Additionally, a successful cyber-attack against a pipeline which supplies our LNG facilities could affect our ability to obtain physical delivery of sufficient natural gas to operate at full capacity, or at all. For example, the operator of the Colonial Pipeline, an unrelated third-party, was forced to pay $4.4 million in ransom to hackers as the result of a cyber-attack disabling the pipeline for several days in May 2021. The attack also resulted in gasoline price increases and shortages across the East Coast of the United States.

Other exposure to various types of cyber-attacks, such as malware, ransomware, viruses, denial of service attacks, social engineering, password spraying, credential stuffing, phishing or other malicious or fraudulent acts, as well as human error or malfeasance, could also potentially disrupt our operations. Such security threats are increasing in frequency and sophistication and pose a risk to the security of our IT systems and the confidentiality, availability and integrity of the information we process and maintain. We also may be vulnerable to interruption and breakdown by fire, natural disaster, power loss, telecommunication failures, internet failures and other catastrophic events. We may experience occasional system interruptions and delays that make our IT systems unavailable or slow to respond, including the interaction of our IT systems with those of third parties.

Cybersecurity threats are persistent and evolve quickly, and we may in the future experience such threats. Such threats have increased in frequency, scope and potential impact in recent years because of the proliferation

 

80


Table of Contents

of new technologies, including artificial intelligence, and the increased number, sophistication and activities of perpetrators of cyber-attacks. Since the techniques used to obtain unauthorized access to or to sabotage IT systems change frequently and are often not recognized until after they are launched against a target, we may be unable to anticipate these techniques or to implement adequate preventative measures. A major cyber incident could result in significant expenses to investigate and repair security breaches or system damage and could lead to litigation, fines, other remedial action, heightened regulatory scrutiny and damage to our reputation and customer relationships. We maintain and update a cybersecurity program to safeguard our IT systems, including those that run and connect to IT systems that run our natural gas liquefaction and export facilities. Failure to continue to do so effectively could expose our IT systems to increased risk of a successful cyber-attack.

We are also reliant on the security practices of our third-party service providers, business partners, vendors, and suppliers, which may be outside of our direct control. These third parties, and the services provided by these third parties, which may include cloud-based services, are subject to the same risk of experiencing, and have experienced, outages, other failures and security breaches described above. IT systems provided by third parties on which we rely also may be difficult to integrate with other tools due to their complexity, resulting in high data inconsistency and incompatibility. If these third parties fail to adhere to adequate security practices, or experience a breach of their systems, the information of our employees, consumers and business associates may be improperly accessed, used, disclosed or otherwise processed, and we may potentially be held liable, or alleged to be liable, under certain laws or contractual obligations for the acts or omissions of our third-party providers. Any loss or interruption to our IT systems or the services provided by third parties could adversely affect our business, financial condition and results of operations.

We maintain property and casualty insurance that may cover certain damage caused by potential cybersecurity incidents. However, other damage and claims arising from such incidents may not be covered or may exceed the amount of any insurance available as discussed under “—Risks Relating to Our Business—We will be unable to insure against all potential risks and may become subject to higher than expected insurance premiums. In addition, we retain certain risks as a result of insurance through our captive insurance.” As a result, a significant cyber incident involving our business or operational control systems or related infrastructure, or that of third-party pipelines with which we do business, could negatively impact our operations, result in data security breaches, impede the processing of transactions, delay financial or compliance reporting or otherwise disrupt our business. These impacts could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Changes in laws, rules or regulations relating to data privacy and security, or any actual or perceived failure by us to comply with such laws, rules and regulations, or contractual or other obligations relating to data privacy and security, could adversely impact our business.

We are, and may increasingly become, subject to various laws, directives, industry standards, rules and regulations, as well as contractual obligations, related to data privacy and security in the jurisdictions in which we operate. The regulatory environment related to data privacy and security is increasingly rigorous, with new and constantly changing requirements, and is likely to remain uncertain for the foreseeable future. These laws, rules and regulations may be interpreted and applied differently over time and from jurisdiction to jurisdiction, and it is possible that they will be interpreted and applied in ways that may have a material adverse effect on our results of operations, financial condition and cash flows.

In the United States, various federal and state regulators, including governmental agencies like the Federal Trade Commission, have adopted, or are considering adopting, laws, rules and regulations concerning personal information. Certain state laws may be more stringent or broader in scope, or offer greater individual rights, with respect to personal information than federal, international or other state laws, and such laws may differ from each other, all of which may complicate compliance efforts. A number of similar laws in other states have already taken effect or will become effective in the near future. State laws are changing rapidly and there is discussion in Congress of a new comprehensive federal data protection law, which may add additional complexity, variation in requirements, restrictions and potential legal risks.

 

81


Table of Contents

All of these evolving compliance and operational requirements impose significant costs on us, which are likely to increase over time. Any failure or perceived failure by us to comply with any applicable federal, state or similar foreign laws, rules and regulations relating to data privacy and security could result in damage to our reputation and our relationship with our customers, as well as proceedings or litigation by governmental agencies or individuals, including class action privacy litigation in certain jurisdictions, which could subject us to significant fines, sanctions, awards, penalties or judgments, operational changes, and negative publicity that could adversely affect our reputation, results of operations and financial condition.

If we are unable to obtain, maintain, protect and enforce our intellectual property rights, our business may be adversely affected.

We rely on a combination of intellectual property rights, including know-how and trade secrets, to establish, maintain and protect our intellectual property and other proprietary rights. For example, under our agreements with Baker Hughes, we own certain know-how and trade secrets relating to aspects of the liquefaction systems, including the routing of the piping and valves within the liquefaction modules and optimization of other module designs, the sharing of supporting equipment between individual liquefaction trains, and the management of mixed refrigerant in the liquefaction process.

We cannot guarantee that our efforts to obtain, maintain, protect and enforce such rights are adequate or that we have secured, or will be able to secure, appropriate permissions or protections for all of the intellectual property rights we use or rely on. Furthermore, any such intellectual property rights may be challenged, invalidated, circumvented, infringed, misappropriated or otherwise violated. Any challenge to our intellectual property rights could result in them being narrowed in scope or declared invalid or unenforceable. In addition, other parties may independently develop technologies that are substantially similar or superior to ours and we may not be able to stop such parties from using such independently developed technologies to compete with us. If we fail to adequately obtain, maintain, protect and enforce our intellectual property rights, we may lose an important advantage in the markets in which we compete. While we seek to enter into confidentiality, intellectual property assignment and non-compete agreements, as applicable, with our employees, contractors and other third parties, we may fail to enter into such agreements with all relevant parties, such agreements may not be self-executing or enforceable, and we may be subject to claims that such parties have misappropriated the trade secrets or other intellectual property or proprietary rights of their former employers or other third parties. Additionally, these agreements may not provide meaningful protection for our trade secrets and know-how in the event of unauthorized use or disclosure.

We also may be forced to bring claims against third parties to determine the ownership of what we regard as our intellectual property or to enforce our intellectual property against its infringement, misappropriation or other violation by third parties. Additionally, third parties may initiate legal proceedings alleging that we are infringing, misappropriating or otherwise violating their intellectual property rights. The outcomes of such intellectual property-related proceedings are often unpredictable. Regardless of whether any such proceedings are resolved in our favor, such proceedings could cause us to incur significant expenses and could distract our personnel from their normal responsibilities. Furthermore, our intellectual property rights and the enforcement or defense of such rights may be affected by developments or uncertainty in laws, rules and regulations related to intellectual property rights. Any of the foregoing could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Risks Relating to this Offering and Ownership of Our Class A Common Stock

VG Partners will continue to have significant influence over us after this offering, including control over decisions that require their approval, which could limit your ability to influence the outcome of key transactions, including a change of control.

Our Class B common stock has ten votes per share and our Class A common stock, which is the stock we are offering in this offering, has one vote per share. Holders of shares of our Class B common stock will vote

 

82


Table of Contents

together with holders of our Class A common stock as a single class on all matters on which stockholders are entitled to vote generally, except as otherwise required by law. See “Description of Capital Stock—Common Stock.” Following this offering, VG Partners will beneficially own     shares of Class B common stock or 100% of all shares of Class B common stock then outstanding. As a result, VG Partners will hold approximately     % of the combined voting power of our Class A common stock and our Class B common stock, or approximately   % of the total combined voting power if the underwriters exercise in full their option to purchase additional shares of our Class A common stock and will be able to influence or control matters requiring approval by our stockholders, including the election of directors and the approval of mergers or other extraordinary transactions. Further, the share of combined voting power held by VG Partners may increase in the future as a result of any repurchase of outstanding Class A common stock that we may decide to pursue from time to time, or any acquisition of our Class A common stock by VG Partners or our Founders, who control VG Partners (including upon vesting or exercise of equity awards). Furthermore, under Delaware law and our amended and restated certificate of incorporation and amended and restated bylaws, VG Partners will be able to take certain actions by written consent of the majority of the combined voting power of our common stock without calling a meeting of stockholders. In addition, as the holder of a majority of the combined voting power of our common stock, VG Partners will initially have the sole ability to elect the board of directors. Other holders of our Class A common stock will, so long as they do not own a majority of the combined voting power, have only minority voting rights on matters affecting our business.

VG Partners may have interests that do not align with the interests of our other stockholders, including with regard to pursuing acquisitions, divestitures, and other transactions that, in their judgment, could enhance their equity investment, even though such transactions might involve risks to our other stockholders. VG Partners will have effective control over our decisions to enter into such corporate transactions regardless of whether others believe that the transaction is in our best interests. Such concentration of voting control may have the effect of delaying, preventing, or deterring a change of control of us, could deprive stockholders of an opportunity to receive a premium for their Class A common stock as part of a sale of us, and might ultimately affect the market price of our Class A common stock. See “Description of Capital Stock.”

An active, liquid trading market for our Class A common stock may not develop or be sustained, and there is the possibility of significant fluctuations in the price of our Class A common stock.

Prior to this offering, there has been no public market for shares of our Class A common stock. We cannot predict the extent to which investor interest in our company will lead to the development of an active trading market on NYSE or how liquid that market may become. If an active trading market does not develop, the market for and liquidity of shares of our Class A common stock may be adversely affected and you may have difficulty selling any of our Class A common stock that you purchase. The initial public offering price of shares of our Class A common stock is, or will be, determined by negotiation between us and the underwriters and may not be indicative of prices that will prevail following the completion of this offering. The market price of shares of our Class A common stock may decline below the initial public offering price, and you may not be able to resell your shares of our Class A common stock at or above the initial public offering price. We cannot assure you as to:

 

   

the likelihood that an active market will develop for our Class A common stock;

 

   

the liquidity of any such market;

 

   

the ability for you to sell your Class A common stock;

 

   

the price that you may obtain for your Class A common stock;

 

   

if an active market does develop, we cannot assure you as to how long such market will be sustained, if at all;

 

   

the price of LNG and natural gas;

 

   

the completion of the regulatory approval process required to construct and operate our projects and the timing of any such completion;

 

83


Table of Contents
   

the commencement and timely completion of construction of our projects;

 

   

our quarterly or annual earnings or those of other companies in our industry;

 

   

actual or potential non-performance by any customer under any LNG sales contract that we may enter into;

 

   

announcements by us or our competitors of significant contracts;

 

   

changes in accounting standards, policies, guidance, interpretations or principles;

 

   

market conditions in the broader stock market in general, or in our industry in particular;

 

   

the failure of securities analysts to cover our Class A common stock after this offering or changes in financial or other estimates by analysts;

 

   

future sales of our Class A common stock;

 

   

regulatory developments;

 

   

litigation and governmental investigations; and

 

   

other factors described in these “Risk Factors” and elsewhere in this prospectus.

These and other factors may cause the market price and demand for our Class A common stock to fluctuate substantially, which may limit or prevent investors from readily selling their shares of our Class A common stock and may otherwise negatively affect the liquidity of our Class A common stock. Accordingly, any investor may lose money or their investment in us and may be required to hold their shares for an indefinite period of time. In addition, in the past, when the market price of a stock has been volatile, holders of that stock have instituted securities class action litigation against the company that issued the stock. If any of our stockholders brought a lawsuit against us, we could incur substantial costs defending the lawsuit. Such a lawsuit could also divert the time and attention of our management from our business.

The trading market for our Class A common stock will also be influenced by the research and reports that industry or securities analysts publish about us or our business. If one or more of these analysts cease coverage of our company or fail to publish reports on us regularly, we could lose visibility in the financial markets, which in turn could cause our stock price or trading volume to decline. Moreover, if one or more of the analysts who cover us downgrade our stock, or if our results of operations do not meet their expectations, our stock price could decline.

If we become a United States real property holding corporation, or a USRPHC, non-U.S. shareholders may be subject to U.S. federal income tax in connection with the disposition of shares of our Class A common stock.

A non-U.S. holder of our Class A common stock not otherwise subject to U.S. federal income tax on gain from the sale or other disposition of our Class A common stock may nevertheless be subject to U.S. federal income tax with respect to such sale or other disposition if we are a USRPHC at any time within the five-year period preceding the sale or other disposition (or the non-U.S. holder’s holding period, if shorter). Generally, a U.S. corporation is a USRPHC if the fair market value of its “United States real property interests,” as defined in the Internal Revenue Code of 1986, as amended, or the Code, and applicable Treasury Regulations, equals or exceeds 50% of the aggregate fair market value of its worldwide real property interests and its other assets used or held for use in a trade or business. Based on the current composition of our assets, we believe that we are not currently a USRPHC. However, because (i) the determination of whether we are a USRPHC at any time depends on the fair market value of our U.S. real property relative to the fair market value of other business assets at such time, and (ii) the determination as to whether certain of our assets, including our property, plant and equipment, constitute United States real property interests, as defined in the Code, may be uncertain, there can be no assurance that we will not become a USRPHC at any point in time in the future. If we were to become a

 

84


Table of Contents

USRPHC at any point during the shorter of (i) the five-year period preceding the sale or other disposition and (ii) the non-U.S. holder’s holding period, and either (1) our Class A common stock is not regularly traded on an established securities market during the calendar year in which the sale or disposition occurs or (2) the non-U.S. holder has owned or is deemed to have owned, at any time within the relevant period, more than 5% of our Class A common stock, the non-U.S. holder would be subject to tax on the net gain from the sale or other disposition under the regular graduated U.S. federal income tax rates applicable to U.S. persons and could, under certain circumstances, be subject to withholding at a 15% rate on the amount realized. See “Material U.S. Federal Income and Estate Tax Consequences for Non-U.S. Holders of Common Stock.”

New investors in our Class A common stock will experience immediate and substantial book value dilution after this offering.

The initial public offering price of our Class A common stock will be higher than the pro forma net tangible book value per share of the outstanding Class A common stock immediately after the offering. Based on an assumed initial public offering price of $    per share (the midpoint of the price range set forth on the cover of this prospectus) and our net tangible book value as of September 30, 2024, if you purchase our Class A common stock in this offering you will pay more for your shares than the amounts paid by our existing stockholders for their shares and you will suffer immediate dilution of approximately $     per share in pro forma net tangible book value. As a result of this dilution, investors purchasing stock in this offering may receive significantly less than the full purchase price that they paid for the shares purchased in this offering in the event of a liquidation.

At the time of this offering, we expect to have approximately    outstanding stock options to purchase Class A common stock with a weighted average exercise price of $    , including the IPO Grants we expect to grant in connection with this offering to certain of our employees under our new omnibus incentive plan, or the 2024 Plan, with an exercise price per share equal to the initial public offering price. To the extent that these options are exercised, there will be further dilution.

We cannot predict the impact our dual class structure may have on the market price of our Class A common stock, especially given restrictions on companies with multiple class structures from certain index providers.

We cannot predict whether our dual class structure will result in a lower or more volatile market price of our Class A common stock, in adverse publicity or other adverse consequences. Certain index providers have announced restrictions on including companies with multiple class share structures in certain of their indices. For example, FTSE Russell does not allow most newly public companies utilizing dual or multi-class capital structures to be included in their indices and while S&P Dow Jones Indices previously did not allow companies with multiple class share structures in certain of their indices, they have since announced that companies with multiple share class structures will be considered eligible for the S&P Composite 1500 and its component indices, including the S&P 500, the S&P MidCap 400 and the S&P SmallCap 600, if they meet all other eligibility criteria.

Under these policies, our dual class capital structure would make us ineligible for inclusion in such indices. Given the sustained flow of investment funds into passive strategies that seek to track certain indices, exclusion from stock indices would likely preclude investment by many of these funds and could make our Class A common stock less attractive to other investors. Additionally, proxy advisory firms have expressed opposition to dual class share structures, stating that they would recommend voting against the management of companies with such dual class share structures and unequal voting rights when the companies did not provide for a reasonable sunset of such structures. As a result, the market price of our Class A common stock could be materially adversely affected.

 

85


Table of Contents

Certain provisions of our amended and restated certificate of incorporation and amended and restated bylaws may have anti-takeover effects, which could limit the price investors might be willing to pay in the future for our Class A common stock. In addition, Delaware law may inhibit takeovers of us and could limit our ability to engage in certain strategic transactions our board of directors believes would be in the best interests of stockholders.

Certain provisions of our amended and restated certificate of incorporation and amended and restated bylaws that will be effective following completion of this offering could discourage unsolicited takeover proposals that stockholders might consider to be in their best interests. Among other things, our amended and restated certificate of incorporation and amended and restated bylaws will include provisions that, among other things:

 

   

provide for a classified board of directors with staggered three-year terms (except that prior to the Trigger Date, our board of directors will consist of a single class of directors each serving one year terms);

 

   

permit directors to be removed from the board of directors by our stockholders only for cause and with the affirmative vote of at least 75% of the combined voting power of our then-outstanding common stock (except that prior to the Trigger Date, directors may be removed by our stockholders with or without cause);

 

   

do not permit cumulative voting in the election of directors, which would otherwise allow less than a majority of stockholders to elect director candidates;

 

   

authorize the issuance of “blank check” preferred stock without any need for action by stockholders;

 

   

limit the ability of stockholders to call special meetings of stockholders or to act by written consent in lieu of a meeting (except that prior to the Trigger Date, special meetings of stockholders may be called by stockholders holding a majority of the combined voting power of our then-outstanding common stock and shareholder actions may be taken by written consent in lieu of a meeting);

 

   

require the affirmative vote of at least 75% of the combined voting power of our then-outstanding common stock, voting as a single class, to amend certain provisions of our certificate of incorporation (except that prior to the Trigger Date, such amendments require only the affirmative vote of a majority of the outstanding shares of common stock); and

 

   

establish advance notice requirements for nominations for election to our board of directors or for proposing matters that may be acted on by stockholders at stockholder meetings; provided that, at any time when VG Partners and its permitted transferees beneficially own, in the aggregate, at least 5% of the combined voting power of our common stock, such advance notice procedure will not apply to VG Partners and its permitted transferees.

The foregoing factors, as well as the significant common stock ownership by VG Partners, could impede a merger, takeover, or other business combination or discourage a potential investor from making a tender offer for our common stock, which, under certain circumstances, could reduce the market value of our Class A common stock. See “Description of Capital Stock.”

In addition, we have expressly elected not to be governed by the “Business Combination” provisions of Section 203 of the Delaware General Corporation Law, or the DGCL, until the earlier of the time at which (i) VG Partners and its permitted transferees no longer beneficially own at least 15% of the combined voting power of our then-outstanding common stock and (ii) our board of directors determines that we will be subject to Section 203 of the DGCL and gives written notice to VG Partners that VG Partners and its permitted transferees shall not be subject to Section 203 of the DGCL. Section 203 of the DGCL generally prohibits a Delaware corporation from engaging in any of a broad range of business combinations with any interested stockholder for a period of three years following the date on which the stockholder became an interested stockholder. If at any time we become subject to the provisions of Section 203 of the DGCL, these provisions will prohibit large stockholders,

 

86


Table of Contents

in particular a stockholder owning 15% or more of the outstanding voting power, from consummating a merger or combination with our company from a three-year period beginning on the date of the transaction in which the stockholder acquired in excess of 15% of our outstanding voting stock, unless this stockholder receives board approval for the transaction or 662/3% of the combined voting power of our then-outstanding common stock not owned by the stockholder approve the merger or transaction. These provisions of Delaware law may have the effect of delaying, deferring or preventing a change in control, and may discourage bids for our Class A common stock at a premium over our market price.

We cannot guarantee that we will pay further dividends on our Class A common stock in the future and, consequently, your ability to achieve a return on your investment will depend on appreciation in the price of our Class A common stock.

While we currently have declared certain cash dividends that remain payable and expect that we will declare and pay additional cash dividends on our common stock from time to time, we cannot guarantee that we will pay dividends on our Class A common stock in the future. The Company is a holding company and has no direct operations. All of our business operations are conducted through our subsidiaries. We cannot assure you that we will pay any dividend in the same amount or frequency as previous dividends, or at all, in the future. Any future dividend payments are within the absolute discretion of our board of directors and will depend on, among other things, our results of operations, working capital requirements, capital expenditure requirements, financial condition, level of indebtedness, contractual restrictions with respect to payment of dividends, business opportunities, anticipated cash needs, provisions of applicable law and other factors that our board of directors may deem relevant. Consequently, your ability to achieve a return on your investment could depend on the appreciation of our Class A common stock. Accordingly, you should not purchase shares of our common stock with the expectation of receiving cash dividends.

Further, Delaware law requires that dividends be paid only out of “surplus,” which is defined as the fair market value of our net assets, minus our stated capital; or out of the current or the immediately preceding year’s earnings. In addition, our ability to pay dividends is subject to a range of restrictions and limitations set forth in the instruments governing our indebtedness and preferred equity. For more details, see “Management’s Discussion and Analysis of Financial Condition and Results of Operations—Liquidity and Capital Resources,” “Risk Factors—Risks Related to Our Indebtedness and Financing—Certain of our debt agreements impose significant operating and financial restrictions on our subsidiaries, and the preferred equity of our subsidiaries also gives the holders certain consent rights, all of which may prevent us from capitalizing on business opportunities or paying dividends to the Company” and “Risk Factors—Risks Related to Our Indebtedness and Financing—As a holding company, the Company depends on the ability of its subsidiaries to transfer funds to it to meet its obligations.”

If we, VG Partners or certain other stockholders sell additional shares of our Class A common stock after this offering or are perceived by the public markets as intending to sell them, the market price of our Class A common stock could decline.

The sale of substantial amounts of shares of our Class A common stock in the public market, or the perception that such sales could occur, could harm the prevailing market price of shares of our Class A common stock. These sales, or the possibility that these sales may occur, also might make it more difficult for us to sell shares of our Class A common stock in the future at a time and at a price that we deem appropriate.

Upon completion of this offering, we will have a total of      shares of our Class A common stock outstanding or      shares, if the underwriters exercise in full their option to purchase additional shares of our Class A common stock, of which      shares will be held by our Pre-IPO Stockholders and      shares (or      shares if the underwriters exercise in full their option to purchase additional shares of our Class A common stock) will have been sold in this offering, and we expect to have approximately      outstanding stock options to purchase Class A common stock. All of the shares of our Class A common stock

 

87


Table of Contents

sold in this offering will be freely tradable without restriction or further registration under the Securities Act of 1933, as amended, or the Securities Act, by persons other than our “affiliates,” as that term is defined under Rule 144 of the Securities Act. See “Shares Eligible for Future Sale.”

In addition, upon completion of this offering, an aggregate of      shares of our Class B common stock will be outstanding, all of which will be held by VG Partners. All such Class B shares of common stock are convertible into our Class A common stock on a one-to-one basis at any time at the option of the holder thereof.

We expect VG Partners will continue to be considered an affiliate following this offering, and accordingly shares of our Class A common stock issued upon conversion of our Class B common stock may not be sold in the absence of registration under the Securities Act unless an exemption from registration is available, including the exemptions contained in Rule 144.

We, our directors and officers, and our Pre-IPO Stockholders are subject to lock-up restrictions pursuant to which, subject to certain exceptions, they may not offer, pledge, sell, contract to sell, sell any option or contract to purchase, purchase any option or contract to sell, grant any option, right or warrant to purchase, lend or otherwise transfer or dispose of, directly or indirectly, any shares of our Class A common stock or securities convertible into or exchangeable for shares of our Class A common stock (including our Class B common stock) for 180 days from the date of this prospectus, except with the prior written consent of the representatives of the underwriters for this offering. See “Underwriting.” In addition, holders of options to purchase Class A common stock outstanding immediately prior to closing of this offering (other than the IPO Grants) are subject to certain market stand-off provisions pursuant to the 2023 Plan, for 180 days from the date of this prospectus, except with prior written consent of us or the underwriters. Upon the expiration of such lock-up arrangements and market stand-off provisions, all of such shares will be eligible for resale in the public market, subject, in the case of shares held by our affiliates, to volume, manner of sale and other limitations under Rule 144. We expect VG Partners will continue to be considered an affiliate following the expiration of the lock-up period based on its expected share ownership. However, subject to the expiration or waiver of the lock-up period, VG Partners, as well as the other Pre-IPO Stockholders, will have the right, subject to certain exceptions and conditions, to require us to register their shares of Class A common stock under the Securities Act, and they will have the right to participate in future registrations of securities by us. Registration of any of these outstanding shares of common stock would result in such shares becoming freely tradable without compliance with Rule 144 upon effectiveness of the registration statement. See “Shares Eligible for Future Sale—Registration Rights” and “Certain Relationships and Related Person Transactions—Existing Shareholders’ Agreement.”

The representatives of the underwriters for this offering, in their sole discretion, may release securities subject to the lock-up arrangements described above in whole or in part at any time; provided that, if release is granted for a stockholder that is one of our officers or directors, the representatives of the underwriters for this offering, on behalf of the underwriters, will notify us of the impending release or waiver at least three business days before the release or waiver, and we have agreed to announce the impending release or waiver at least two business days before the effective date of the release or waiver.

We intend to file one or more registration statements on Form S-8 under the Securities Act to register shares of our Class A common stock issuable under our outstanding stock options to purchase Class A common stock and the shares of our Class A common stock reserved for issuance under the 2024 Plan. Any such Form S-8 registration statements will automatically become effective upon filing. Accordingly, shares registered under such registration statements will be available for sale in the open market. If such shares of Class A common stock are sold or it is perceived that they will be sold in the public market, the trading price of our Class A common stock could decline. These sales also could impede our ability to raise future capital.

You may be diluted by the future issuance of additional Class A common stock, including in connection with our incentive plans, acquisitions, conversion of our Class B common stock, or otherwise.

After this offering we will have     shares of Class A common stock authorized but unissued. Our amended and restated certificate of incorporation authorizes us to issue these shares of Class A common stock

 

88


Table of Contents

and options, rights, warrants and appreciation rights relating to Class A common stock for the consideration and on the terms and conditions established by our board of directors in its sole discretion, whether in connection with incentive plans, acquisitions or otherwise. For additional information concerning the awards under the 2023 Plan, including those that will be outstanding at the time of this offering, and the awards under the 2024 Plan, including those that we intend to grant in connection with this offering, see “Summary—The Offering.”

Additionally, shares of our Class B common stock are convertible into shares of our Class A common stock on a one-for-one basis at the option of the holder. Moreover, future transfers, except for certain permitted transfers described in our amended and restated certificate of incorporation, by VG Partners of shares of Class B common stock will generally result in those shares automatically converting into shares of Class A common stock on a one-for-one basis. The conversion of Class B common stock into Class A common stock as a result of such exchanges or transfers would dilute holders of Class A common stock, including holders of shares purchased in this offering, in terms of the number of outstanding shares of Class A common stock and voting power within Class A common stock.

Any Class A common stock that we issue, including under our existing equity incentive plans or other equity incentive plans that we may adopt in the future, would dilute the percentage ownership held by the investors who purchase Class A common stock in this offering. For example, in connection with this offering, we intend to file one or more registration statements on Form S-8 under the Securities Act to register shares of our Class A common stock issuable under our outstanding stock options to purchase Class A common stock and the shares of our Class A common stock reserved for issuance under our 2024 Plan. It is anticipated that additional equity awards will be granted to our employees and directors following the completion of this offering, from time to time, under the 2024 Plan and other equity incentive plants that we may adopt in the future.

We cannot predict with certainty the size of future issuances of shares of our Class A common stock or the effect, if any, that future issuances and sales of shares of our Class A common stock will have on the market price of shares of our common stock. Any such issuance could result in substantial dilution to our existing stockholders.

We may issue preferred stock whose terms could materially adversely affect the voting power or value of our Class A common stock.

Our amended and restated certificate of incorporation will authorize us to issue, without the approval of our stockholders, one or more classes or series of preferred stock having such designations, preferences, limitations and relative rights, including preferences over our Class A common stock respecting dividends and distributions, as our board of directors may determine. The terms of one or more classes or series of preferred stock could adversely impact the voting power or value of our Class A common stock. For example, we might grant holders of preferred stock the right to elect some number of our directors in all events or on the happening of specified events or the right to veto specified transactions. Similarly, the repurchase or redemption rights or liquidation preferences we might assign to holders of preferred stock could affect the residual value of the Class A common stock. See “Description of Capital Stock.”

If our estimates or judgments relating to our critical accounting policies are based on assumptions that change or estimates that prove to be incorrect, our results of operations could be adversely affected, which could cause the price of our Class A common stock to decline.

The preparation of financial statements in conformity with GAAP requires management to make estimates and assumptions that affect the amounts reported in our financial statements and the accompanying notes thereto. We base our estimates on historical experience and on various other assumptions that we believe to be reasonable under the circumstances, the results of which form the basis for making judgments about the carrying values of assets, liabilities, equity, revenue and expenses that are not readily apparent from other sources. It is possible that interpretation, industry practice and guidance involving estimates and assumptions may evolve or change over

 

89


Table of Contents

time. If our assumptions change, or if actual circumstances differ from our assumptions, our results of operations may be adversely affected, which could cause the price of our Class A common stock to decline.

We have broad discretion in the use of our net proceeds from this offering and may not use them effectively.

Our management will have broad discretion in the application of the net proceeds from this offering and could spend the proceeds in ways that do not improve our operating results or enhance the value of our Class A common stock. Our stockholders may not agree with the manner in which our management chooses to allocate and spend the net proceeds. Our management’s failure to apply these funds effectively could result in financial losses that could have a material adverse effect on our business and cause the price of our Class A common stock to decline. Pending their use, we may invest our net proceeds from this offering in a manner that does not produce income or that loses value. See “Use of Proceeds.”

We will incur increased costs and become subject to additional regulations and requirements as a result of becoming a public company, which could lower our profits, make it more difficult to run our business or divert management’s attention from our business.

As a public company, we will be required to commit significant resources and management time and attention to the requirements of being a public company, which will cause us to incur significant legal, accounting and other expenses that we have not incurred as a private company, including costs associated with public company reporting requirements. We also will incur costs associated with the Securities Exchange Act of 1934, as amended, or the Exchange Act, the Sarbanes-Oxley Act of 2002, or the Sarbanes-Oxley Act, the Dodd-Frank Wall Street Reform and Protection Act, and related rules implemented by the Securities and Exchange Commission, or the SEC, and the NYSE, and compliance with these requirements will place significant demands on our legal, accounting and finance staff and on our accounting, financial and information systems. Although we have a number of directors, officers and employees with experience in complying with these requirements applicable to public companies, there can be no assurance that we will be successful in complying with these requirements. The expenses incurred by public companies generally for reporting and corporate governance purposes have been increasing. We expect these rules and regulations to increase our legal and financial compliance costs and to make some activities more time-consuming and costly, although we are currently unable to estimate these costs with any degree of certainty. These laws and regulations also could make it more difficult or costly for us to obtain certain types of insurance, including director and officer liability insurance, and we may be forced to accept reduced policy limits and coverage, higher retention, or incur substantially higher costs to obtain the same or similar coverage. These laws and regulations could also make it more difficult for us to attract and retain qualified persons to serve on our board of directors, our board committees or as our executive officers. Furthermore, if we are unable to satisfy our obligations as a public company, we could be subject to delisting of our Class A common stock, fines, sanctions and other regulatory action and potentially civil litigation.

As a result of being a public company, we are obligated to develop and maintain proper and effective internal controls over financial reporting, and any failure to maintain the adequacy of these internal controls may adversely affect investor confidence in our company and, as a result, the value of our Class A common stock.

We are required, pursuant to Section 404 of the Sarbanes-Oxley Act, to furnish a report by management on, among other things, the effectiveness of our internal control over financial reporting for the fiscal year ending December 31, 2025. This assessment will need to include disclosure of any material weaknesses identified by our management in our internal control over financial reporting. In addition, our independent registered public accounting firm will be required to attest to the effectiveness of our internal control over financial reporting in our annual report required to be filed with the SEC for the fiscal year ending December 31, 2026. We have recently commenced the costly and challenging process of compiling the system and processing documentation necessary to perform the evaluation needed to comply with Section 404 of the Sarbanes-Oxley Act, but we may not be able to complete our evaluation, testing and any required remediation in a timely fashion once initiated.

 

90


Table of Contents

Our compliance with Section 404 of the Sarbanes-Oxley Act will require that we incur substantial expenses and expend significant management efforts. We currently do not have an internal audit group, and we will need to hire additional accounting and financial staff with appropriate public company experience and technical accounting knowledge and compile the system and process documentation necessary to perform the evaluation needed to comply with Section 404 of the Sarbanes-Oxley Act.

During the evaluation and testing process of our internal controls, if we identify one or more material weaknesses in our internal control over financial reporting, we will be unable to certify that our internal control over financial reporting is effective. We cannot assure you that there will not be material weaknesses or significant deficiencies in our internal control over financial reporting in the future. Any failure to maintain internal control over financial reporting could severely inhibit our ability to accurately report our financial condition or results of operations. If we are unable to conclude that our internal control over financial reporting is effective, or if our independent registered public accounting firm determines we have a material weakness or significant deficiency in our internal control over financial reporting, we could lose investor confidence in the accuracy and completeness of our financial reports, the market price of our Class A common stock could decline, and we could be subject to sanctions or investigations by the SEC or other regulatory authorities. Failure to remedy any material weakness in our internal control over financial reporting, or to implement or maintain other effective control systems required of public companies, could also restrict our future access to the capital markets.

Upon the listing of our Class A common stock on the NYSE, we will be a “controlled company” within the meaning of the NYSE rules and, as a result, will qualify for exemptions from certain corporate governance requirements. If we rely on such exemptions in the future, you will not have the same protections afforded to stockholders of companies that are subject to such requirements.

Upon completion of this offering, VG Partners will continue to control a majority of the voting power of our outstanding common stock, and we will be a “controlled company” within the meaning of the NYSE corporate governance standards. Under the NYSE rules, a company of which more than 50% of the voting power is held by another person or group of persons acting together is a “controlled company” and may elect not to comply with certain NYSE corporate governance requirements, including the requirements that:

 

   

a majority of the board of directors consist of independent directors;

 

   

the nominating and corporate governance committee be composed entirely of independent directors with a written charter addressing the committee’s purpose and responsibilities;

 

   

the compensation committee be composed entirely of independent directors with a written charter addressing the committee’s purpose and responsibilities; and

 

   

there be an annual performance evaluation of the nominating and corporate governance and compensation committees.

Consistent with these exemptions, upon closing this offering, we will not have an independent compensation committee or an independent nominating and corporate governance committee. Accordingly, you may not have the same protections afforded to stockholders of companies that are subject to all of the NYSE corporate governance requirements.

Our amended and restated certificate of incorporation will designate the Court of Chancery of the State of Delaware or the federal district courts of the United States of America, as applicable, as the sole and exclusive forum for certain types of actions and proceedings that may be initiated by our stockholders, which could limit our stockholders’ ability to obtain a favorable judicial forum for disputes with the Company or the Company’s directors, officers or other employees.

Our amended and restated certificate of incorporation will provide that, unless we consent to the selection of an alternative forum, the Court of Chancery of the State of Delaware will, to the fullest extent permitted by law,

 

91


Table of Contents

be the sole and exclusive forum for: (i) any derivative action or proceeding brought on our behalf; (ii) any action asserting a breach of fiduciary duty owed by any current or former director, officer, stockholder or employee of the Company to the Company or our stockholders; (iii) any action asserting a claim against us arising under the Delaware General Corporation Law, or the DGCL, our certificate of incorporation or our bylaws or as to which the DGCL confers jurisdiction on the Court of Chancery of the State of Delaware; or (iv) any action asserting a claim against us that is governed by the internal affairs doctrine.

These provisions will not apply to suits brought to enforce a duty or liability created by the Exchange Act. Furthermore, Section 22 of the Securities Act, creates concurrent jurisdiction for federal and state courts over all suits brought to enforce any duty or liability created by the Securities Act or the rules and regulations thereunder. Accordingly, both state and federal courts have jurisdiction to entertain such claims. To prevent having to litigate claims in multiple jurisdictions and the threat of inconsistent or contrary rulings by different courts, among other considerations, our amended and restated certificate of incorporation will further provide that the federal district courts of the United States of America will be the exclusive forum for resolving any complaint asserting a cause or causes of action arising under the Securities Act, including all causes of action asserted against any defendant to such complaint. While the Delaware courts have determined that such choice of forum provisions are facially valid, a stockholder may nevertheless seek to bring a claim in a venue other than those designated in the exclusive forum provisions and there can be no assurance that these provisions will be enforced by a court in those other jurisdictions. In this regard, stockholders may not be deemed to have waived our compliance with the federal securities laws and the rules and regulations thereunder, including Section 22 of the Securities Act.

Any person or entity purchasing or otherwise acquiring any interest in any shares of our capital stock shall be deemed to have notice of and to have consented to the forum provision in our amended and restated certificate of incorporation. This choice-of-forum provision may limit a stockholder’s ability to bring a claim in a different judicial forum, including one that it may find favorable or convenient for a specified class of disputes with the Company or the Company’s directors, officers, other stockholders or employees, which may discourage such lawsuits. Alternatively, if a court were to find this provision of our amended and restated certificate of incorporation inapplicable or unenforceable with respect to one or more of the specified types of actions or proceedings, we may incur additional costs associated with resolving such matters in other jurisdictions, which could materially adversely affect our business, financial condition and results of operations and result in a diversion of the time and resources of our management and board of directors.

General Risk Factors

Global economic conditions, including inflation and supply chain disruptions, could continue to adversely affect our operations.

General global economic downturns and macroeconomic trends, including heightened inflation, capital market volatility, interest rate and currency rate fluctuations, and economic slowdown or recession, may result in unfavorable conditions that could negatively affect demand for our products and exacerbate some of the other risks that affect our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. Both domestic and international markets experienced significant inflationary pressures in fiscal years 2022 and 2023 and inflation rates in the U.S., as well as in other countries in which we operate, may remain at elevated levels for the near-term. In addition, the Federal Reserve in the U.S. and other central banks in various countries have raised, and may again raise, interest rates in response to concerns about inflation, which, coupled with reduced government spending and volatility in financial markets, may have the effect of further increasing economic uncertainty and heightening these risks. Interest rate increases or other government actions taken to reduce inflation could also result in recessionary pressures in many parts of the world. Furthermore, currency exchange rates have been especially volatile in the recent past, and these currency fluctuations have affected, and may continue to affect, the reported value of our assets and liabilities, as well as our cash flows.

 

92


Table of Contents

We have also experienced significant challenges in our global supply chain, including shortages in supply of materials and equipment to complete construction of our projects. While to date, we have been able to manage the challenges associated with these delays and shortages without significant disruption to our business, no assurance can be given that these efforts will continue to be successful. In addition, the deterioration of conditions in global credit markets may limit our ability to obtain, or may increase the cost of, external financing to fund our operations and capital expenditures on terms favorable to us, if at all. If we are unable to obtain adequate financing or financing on terms satisfactory to us, when we require it, we will have to significantly reduce our spending, delay or cancel construction of our projects or substantially change our corporate structure, and we might not have sufficient resources to conduct or support our business as projected, which would have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock. See “—Risks Relating to Our Projects and Other Assets—We will require significant additional capital to construct and complete certain of our projects, and we may not be able to secure such financing on time with acceptable terms, or at all, which could cause delays in our construction, lead to inadequate liquidity and increase overall costs.”

Terrorist attacks, including cyberterrorism, or military campaigns may adversely impact our business.

A terrorism, including a cyberterrorism, or military incident affecting LNG facilities, including our projects, may result in delays in construction, which could increase the cost of completion of our projects beyond the amounts that we have estimated. See “—Risks Relating to Our Projects and Other Assets—Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.” A terrorism, including a cyberterrorism, incident may also result in temporary or permanent closure of any of our projects, which could increase our costs and decrease our cash flows, depending on the duration and timing of the closure. Our operations could also become subject to increased governmental scrutiny that may result in additional security measures at a significant incremental cost to us. In addition, the threat of terrorism, including cyberterrorism, and the impact of military campaigns may lead to continued volatility in prices for natural gas that could adversely affect our business and our customers, including their ability to satisfy their obligations to us under our commercial agreements. Instability in the financial markets as a result of terrorism, including cyberterrorism, war, earthquakes and other natural or man-made disasters, pandemics, credit crises, recessions or other factors could increase the cost of insurance coverage and could also result in a significant decline in the U.S. economy and could also materially adversely affect our ability to raise capital. The continuation of these developments may subject our construction and our operations to increased risks, as well as increased costs, and, depending on their ultimate magnitude, could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

Changes in tax laws or tax rulings, or the examination of our tax positions, could materially affect our financial condition and results of operations.

We are subject to various types of tax arising from normal business operations in the jurisdictions in which we operate and transact. Any changes to local, domestic or international tax laws and regulations, or their interpretation and application, including those with retroactive effect, could affect our tax obligations, profitability and cash flows in the future. In addition, tax rates in the various jurisdictions in which we operate may change significantly due to political or economic factors beyond our control. Our existing corporate structure and intercompany arrangements have been implemented in a manner we believe is in compliance with current prevailing tax laws. In addition, the taxing authorities in the United States and other jurisdictions where we do business regularly examine income and other tax returns and we expect that they may examine our income and other tax returns. The ultimate outcome of these examinations cannot be predicted with certainty. We continuously monitor and assess proposed tax legislation that could negatively impact our business.

The Inflation Reduction Act, enacted on August 16, 2022, includes the implementation of a new 15% corporate alternative minimum tax, or the CAMT, on adjusted financial statement income for applicable

 

93


Table of Contents

corporations, effective for tax years beginning after December 31, 2022. CAMT is a novel and new approach for calculating corporate tax liability. Many unanswered questions remain on how the operative rules for CAMT will be implemented and interpreted. The CAMT may lead to volatility in our cash tax payment obligations, particularly in periods of significant commodity, currency or financial market variability resulting from potential changes in the fair value of our derivative instruments.

We face risks related to the uncertainty regarding the future of international trade agreements and the United States’ position on international trade.

Certain policies and statements of the first Trump administration that may continue in the second Trump administration have given rise to uncertainty regarding the future of international trade agreements and the United States’ position on international trade. For example, the first Trump administration imposed tariffs on a range of products from China, which led China to also impose tariffs on certain U.S. goods in retaliation, including a 25% tariff on U.S. LNG imports. Additionally, President-elect Donald Trump has indicated that he intends to impose tariffs, including a 60% tariff on goods imported from China and a 20% on all other U.S. imports, which could result in retaliatory tariffs imposed on U.S. businesses from China and any other countries affected by such tariffs. At this time, it remains unclear whether the second Trump administration will take such measures and whether such countries, if any, will impose additional burdens on U.S. businesses in return. As of September 30, 2024, we had entered into long-term, post-COD SPAs for an aggregate of 9.5 mtpa with Chinese customers across all of our projects. Any future changes to the United States’ trade relationship with China or other major LNG importing nations, including through the imposition of further tariffs, could have an adverse impact on such SPAs and our ability to market the remaining production capacity of our projects, by reducing demand from such customers for U.S. LNG exports. Moreover, the uncertainty regarding the policies of the second Trump administration with respect to the future of trade partnerships and relations, including the possibility of additional or increased tariffs, may reduce our competitiveness in countries that may be affected by those policies, such as China, whether or not the second Trump administration ultimately takes any such actions. Any of these factors could adversely affect our ability to market the remaining production capacity of our projects, which could have a material adverse effect on the viability of our projects and on our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

The outbreak of any infectious diseases or other illness, including COVID-19 and its variants, could adversely impact our business, contracts, financial condition, operating results, cash flow, financing requirements, liquidity, prospects and the price of our Class A common stock.

We are subject to risks related to outbreaks of infectious diseases, including COVID-19 and its variants. The extent to which an outbreak of an infectious disease or other illness, including COVID-19, could impact our business, operations and financial results depends on numerous factors that we cannot accurately predict, including: the duration and scope of any infectious disease; governmental, business and individuals’ actions taken in response to any infectious disease and the associated impact on economic activity; the effect on the level of global demand for natural gas; geopolitical developments in the oil and gas markets; our ability to procure materials and services from third parties that are necessary for the operation of our business; the effect on the labor market, including worker shortages or related to supply chain disruptions; our ability to provide our services, including as a result of travel restrictions on our employees and employees of third parties that we utilize in connection with our services; the potential for key executives or employees to fall ill; and the ability of our customers to pay for our services if their businesses suffer as a result of any infectious disease.

The factors discussed above could have a material adverse effect on our business, results of operations and financial condition. In addition, certain of our construction contractors and suppliers may attempt to seek contractual relief in response to the impacts of the COVID-19 pandemic, or any future pandemic, on their performance. Any changes arising from such requests could result in delays or increased costs, which could have a material adverse effect on our business.

 

94


Table of Contents

We cannot estimate the magnitude and duration of potential social, economic and labor instability as a direct result of any infectious disease or pandemic. Should any of these potential impacts continue for an extended period of time, it will have a negative impact on the demand for our services and a material adverse effect on our financial position and results of operations. Moreover, the foregoing factors may also have the effect of heightening some of the other risk factors described herein.

Developments related to the ongoing war between Russia and Ukraine and the ongoing conflicts in the Middle East could adversely affect our business, contracts, financial condition, operating results, cash flows, liquidity and prospects.

Russia is one of the main players in the global oil and gas markets. Accordingly, any events that can impair or enhance its ability to compete in such markets are likely to have an impact on the industry in which we operate and the operations of our projects. Since the beginning of Russia’s invasion of Ukraine, sanctions have been imposed by Ukraine’s allies that seek to limit Russia’s ability to profit from oil and gas exports, and certain retaliatory measures have been taken by Russia in response (such as the ban on sales to certain countries). Additionally, there have been publicized threats to increase hacking activity against the critical infrastructure of any nation or organization that retaliates against Russia for its invasion. This invasion, as well as the ongoing conflicts in the Middle East, including the Israel-Hamas conflict and other hostilities in the region have led, are currently leading, and for an unknown period of time will continue to lead to disruptions in local, regional, national, and global markets and economies affected thereby. These disruptions caused by the invasion and such conflicts have included, and may continue to include, political, social, and economic disruptions and uncertainties and material increases in certain commodity prices that could adversely affect our business, contracts, financial condition, operating results, cash flows, liquidity and prospects and the price of our Class A common stock.

 

95


Table of Contents

SPECIAL NOTE REGARDING FORWARD-LOOKING STATEMENTS

We have made statements under the captions “Prospectus Summary,” “Risk Factors,” “Management’s Discussion and Analysis of Financial Condition and Results of Operations,” “Business,” “LNG Industry Overview” and in other sections of this prospectus that are forward-looking statements. All statements, other than statements of historical facts, included herein are “forward-looking statements.” In some cases, forward-looking statements can be identified by terminology such as “may,” “might,” “will,” “could,” “should,” “expect,” “plan,” “project,” “intend,” “anticipate,” “believe,” “estimate,” “predict,” “potential,” “pursue,” “target,” “continue,” the negative of such terms or other comparable terminology.

These forward-looking statements, which are subject to risks, uncertainties and assumptions about us, may include projections of our future financial performance, expectations regarding the development, construction, commissioning and completion of our projects, estimates of the cost of our projects and schedule to construct and commission our projects, our anticipated growth strategies and anticipated trends impacting our business. These statements are only predictions based on our current expectations and projections about future events. There are important factors that could cause our actual results, level of activity, performance or achievements to differ materially from the results, level of activity, performance or achievements expressed or implied by the forward-looking statements, including those factors discussed under the caption entitled “Risk Factors.” Those factors include the following:

 

   

our potential inability to maintain profitability, maintain positive operating cash flow and ensure adequate liquidity in the future;

 

   

our limited track record and historical financial information, and the lack of assurance that our business will continue to be successful;

 

   

our need for significant additional capital to construct and complete some future projects, and our potential inability to secure such financing on acceptable terms, or at all;

 

   

our potential inability to construct or operate all of our proposed LNG facilities or pipelines or any additional LNG facilities or pipelines beyond those currently planned, which could limit our growth prospects;

 

   

significant operational risks related to our natural gas liquefaction and export projects, including the Calcasieu Project, the Plaquemines Project, the CP2 Project, the CP3 Project, the Delta Project, any future projects we develop, our LNG tankers, and our regasification terminal usage rights;

 

   

our potential inability to accurately estimate costs for our projects, and potential changes to our estimates due to various factors;

 

   

potential delays in the construction of our projects beyond the estimated development periods;

 

   

our potential inability to enter into the necessary contracts to construct the CP2 Project, the CP3 Project or the Delta Project on a timely basis or on terms that are acceptable to us;

 

   

the potential that counterparties in certain of our contractual arrangements relating to the development and construction of our projects may exercise their existing termination rights;

 

   

the potential inability of our contractors to perform their obligations under our multiple procurement and construction contracts;

 

   

our potential inability to enter into post-COD SPAs with customers for, or to otherwise sell, an adequate portion of the total expected nameplate capacity at the CP2 Project, the CP3 Project, the Delta Project or any future projects we develop;

 

   

our dependence on our EPC and other contractors for the successful completion of our projects and delivery of our LNG tankers;

 

96


Table of Contents
   

our dependence on third party vendors and service providers for the provision of certain services and equipment to our projects and their potential inability to perform according to the terms of the applicable agreements;

 

   

various economic and political factors, including opposition by environmental or other public interest groups, which could negatively affect the timing or overall development, construction and operation of our projects;

 

   

the effects of FERC regulation on our interstate natural gas pipelines and their FERC gas tariffs;

 

   

our potential inability to secure the right or the potential risk of losing the right to situate the pipelines required for any of our projects on property owned by third parties, or our potential inability to timely complete the construction of those pipelines;

 

   

the potential lack of local government and community support required for the construction of our projects;

 

   

the potential that our real property rights in the sites for our projects or any other natural gas liquefaction and export facilities that we may decide to develop in the future may be adversely affected by the rights of others that are superior to those of the grantors of our real property rights;

 

   

the risk that the natural gas liquefaction system and mid-scale design we utilize at our projects will not achieve the level of performance or other benefits that we anticipate;

 

   

potential additional risks arising from the duration of and the phased commissioning start-up of our projects;

 

   

our potential inability to retain and attract executive officers and other skilled professional and technical employees;

 

   

our dependence on the strategic direction of our founders;

 

   

risks that we or our contractors, including our EPC contractors, may experience increased labor costs, and the unavailability of skilled workers or our potential failure to attract and retain qualified personnel;

 

   

the potential risk that our customers or we may terminate our SPAs if certain conditions are not met or for other reasons;

 

   

our potential inability to generate cash under our post-COD SPAs due to our dependence upon the performance by a limited number of our customers;

 

   

the significant uncertainty in our ability to generate proceeds and the amount of proceeds that will regularly be received from sales of commissioning cargos and excess cargos due to volatility and variability in the LNG markets;

 

   

potential decreases in the price of natural gas and its related impact on our ability to pay the cost of gas transportation, the payment of a premium by us for feed gas relative to the contractual price we charge our customers, or other impacts to the price of natural gas resulting from inflationary pressures;

 

   

our potential inability to sell uncontracted or excess liquefaction capacity or produce LNG in excess of the nameplate capacity of our facilities;

 

   

our reliance on third-party engineers to estimate the future capacity ratings and performance capabilities of our projects, which may prove to be inaccurate;

 

   

our potential inability to purchase or receive physical delivery of sufficient natural gas to satisfy our delivery obligations under our SPAs;

 

   

the potential negative impacts of seasonal fluctuations on our business;

 

   

our limited diversification;

 

97


Table of Contents
   

our potential inability to obtain, maintain or comply with necessary permits or approvals from governmental and regulatory agencies on which the construction of our projects depends, including as a result of opposition by environmental and other public interest groups;

 

   

the risk that the construction and operations of natural gas pipelines and pipeline connections for our projects suffer cost overruns and delays related to obtaining regulatory approvals, development risks, operational hazards and other risks;

 

   

the risk of a reduction of volumes of natural gas transported to our facilities due to any third-party pipelines and other facilities interconnected to our pipelines and facilities becoming unavailable to transport natural gas or suffering any reductions in the capacity of, or the allocations to, interconnecting third-party pipelines;

 

   

the potential of increased costs and liabilities due to pipeline safety integrity programs and repairs;

 

   

our current and potential involvement in disputes and legal proceedings, including the arbitrations and other proceedings currently pending against us and the possibility of a negative outcome in any such dispute or proceeding and the potential impact thereof on our results of operations, liquidity and our existing contracts;

 

   

the risks related to the development and/or contracting for additional gas transportation capacity to support the operation and expansion capacity of our LNG projects;

 

   

the risks related to the chartering, acquisition and/or building of LNG tankers, including the risk of delays in delivery, increases in charter, price or building costs, and ability to raise any capital necessary to finance the chartering, acquisition and/or building of any LNG tankers;

 

   

the risks related to the management and operation of our LNG tanker fleet and our future regasification terminal usage rights;

 

   

the potential that various tax incentive programs the State of Louisiana offers that we plan to utilize may not be available or be available in diminished form;

 

   

the uncertainty regarding the future of international trade agreements and the United States’ position on international trade;

 

   

severe weather events, hurricanes or other disasters which could potentially cause interruptions of our operations, a delay in the completion of our projects, higher construction costs and the deferral of the dates on which we would become entitled to receive payments under any SPAs;

 

   

our potential inability to insure against all potential risks and the risk that we may become subject to higher than expected insurance premiums, as well as risks associated with our captive insurance company;

 

   

the possibility of hostile cyber intrusions;

 

   

our ability to construct LNG facilities that produce LNG at volumes in excess of their nameplate capacity, and our ability to market and sell any such volumes produced by our LNG facilities in excess of their nameplate capacity;

 

   

competition in the LNG industry and the potential that many of our competitors may have greater financial, engineering, marketing and other resources than we have;

 

   

competition based upon the international market price for LNG;

 

   

the potential that LNG exported from the United States fails to remain a competitive source of energy for international markets;

 

   

the potential risk of developments related to the ongoing war between Russia and Ukraine and the ongoing conflicts in the Middle East;

 

98


Table of Contents
   

cyclical or other changes in the demand for and price of LNG and natural gas;

 

   

potential shortages of LNG tankers worldwide;

 

   

the potential that technological innovation may render our anticipated competitive advantage or our processes obsolete;

 

   

the potential effects of existing and future environmental and similar laws and governmental regulations on compliance costs, operating and/or construction costs and restrictions;

 

   

the potential lack of an active, liquid trading market for our Class A common stock, and the possibility of significant fluctuations in the price of our Class A common stock;

 

   

our indebtedness levels, and the fact that we may be able to incur substantially more indebtedness, which may increase the risks created by our substantial indebtedness;

 

   

risks of downgrade, suspension or withdrawal of the rating assigned by a rating agency to us could impact our cost of capital;

 

   

concentration of control over our management, affairs and over matters requiring stockholder approval with VG Partners as a result of the dual class structure of our common stock and VG Partners’ ownership of our Class B common stock;

 

   

potential conflicts of interest with VG Partners or any of its officers, directors, agents, shareholders, members, partners, affiliates or subsidiaries (other than us); and

 

   

risks related to other factors discussed under “Risk Factors” of this prospectus.

You should specifically consider the numerous risks outlined under “Risk Factors.” Moreover, new risks emerge from time to time as we operate in a very competitive and rapidly changing business environment. It is not possible for our management to predict all risks, nor can we assess the impact of all factors on our business or the extent to which any factor, or combination of factors, may cause actual results to differ materially from those contained in any forward-looking statements we may make. Given these uncertainties, you should not place undue reliance on these forward-looking statements.

All such factors are difficult to predict, contain uncertainties that may materially affect actual results and may be beyond our control. New factors emerge from time to time, and it is not possible for management to predict all such factors or to assess the impact of each such factor on us.

Any forward-looking statement speaks only as of the date on which such statement is made, and we do not undertake any obligation to update any forward-looking statement to reflect events or circumstances after the date on which such statement is made except as required by the federal securities laws. If one or more of these or other risks or uncertainties materialize, or if our underlying assumptions prove to be incorrect, our actual results may vary materially from what we may have expressed or implied by these forward-looking statements. We caution that you should not place undue reliance on any of our forward-looking statements. You should specifically consider the factors identified in this prospectus that could cause actual results to differ before making an investment decision to purchase our Class A common stock. Furthermore, new risks and uncertainties arise from time to time, and it is impossible for us to predict those events or how they may affect us.

 

99


Table of Contents

USE OF PROCEEDS

We estimate that the net proceeds to us from this offering will be approximately $   billion, or approximately $   billion if the underwriters exercise their option to purchase additional shares in full, assuming an initial public offering price of $   per share (the midpoint of the range set forth on the cover page of this prospectus), after deducting estimated underwriting discounts and commissions and estimated offering expenses.

The principal purposes of this offering are to support the continued growth and development of our business, increase our financial flexibility, and establish a public market for our Class A common stock. We intend to use the net proceeds from this offering for general corporate purposes, including, but not limited to, funding our expected pre-FID capital expenditures with respect to the CP2 Project, the CP3 Project and the Delta Project, our continuing operations, our LNG tanker milestone payments, and our pipeline development projects. We do not intend to use any portion of the net proceeds from this offering to pay our declared but unpaid dividends described in “Dividend Policy.”

The intended use of net proceeds from this offering represents our intentions based upon our present plans and business conditions. However, we have no current specific plan with regard to the amount of proceeds we will spend on the intended uses set forth above, nor can we predict with certainty all of the particular uses for the proceeds of this offering. Accordingly, our management will have broad discretion in applying the net proceeds of this offering. The timing and amount of our actual expenditures will be based on many factors, including cash flows from operations and the anticipated growth of our business. See “Risk Factors—Risks Relating to this Offering and Ownership of Our Class A Common Stock—We have broad discretion in the use of our net proceeds from this offering and may not use them effectively.”

Each $1.00 increase (decrease) in the public offering price per share would increase (decrease) our net proceeds, after deducting estimated underwriting discounts and commissions, by $   million (assuming the number of shares of our Class A common stock offered by us, as set forth on the cover of this prospectus, remains the same, and assuming no exercise of the underwriters’ option to purchase additional shares). We may also increase or decrease the number of shares we are offering. An increase (decrease) of one million shares in the number of shares of our Class A common stock offered by us would increase (decrease) our net proceeds, after deducting estimated underwriting discounts and commissions, by $   million (assuming the public offering price remains the same, and assuming no exercise of the underwriters’ option to purchase additional shares).

 

100


Table of Contents

DIVIDEND POLICY

On September 13, 2024, our board of directors declared the payment of cash dividends to our stockholders in an aggregate amount of $160 million to be paid, subject to applicable law, on a pro rata basis to holders of record of our outstanding common stock on the applicable record dates in four equal dividend payments of $40 million on the last business day of four consecutive calendar quarters. The purpose of this cash dividend is to distribute profits to our stockholders.

The first two such dividend payments were made, or will be made, respectively, on September 30 and December 31, 2024, to holders of our outstanding common stock of record as of September 13 and December 12, 2024, respectively. Purchasers of shares in this offering will not be entitled to receive these two dividend payments because the record dates for both such dividend payments occurred prior to the completion of this offering. We expect to pay the remaining two dividend payments on the last business day of each of the calendar quarters ending March 31, 2025 and June 30, 2025, on a ratable basis to holders of our outstanding common stock, as of a record date to be determined by us and announced prior to the applicable dividend payment date. We expect that the record date for these two dividend payments will be following the completion of this offering. Our amended and restated certificate of incorporation that will be effective upon the completion of this offering authorizes Class A common stock and Class B common stock and provides that holders of our Class A common stock and holders of our Class B common stock will be treated equally and ratably on a per share basis with respect to any dividends (unless different treatment of the shares of a class is approved by the affirmative vote of the holders of a majority of the outstanding shares of the applicable class of common stock treated adversely, voting separately as a class). Accordingly, purchasers of shares of Class A common stock in this offering that are holders on the applicable record date for each of the remaining two dividend payments of the declared dividend will be entitled to receive such dividend payments. The remaining two dividend payments are not contingent on the completion of this offering.

We currently expect that we will declare and pay additional cash dividends on our common stock from time to time. However, we cannot assure you that we will pay any dividend in the same amount or frequency as previous dividends, or at all, in the future. Any future dividend payments are within the absolute discretion of our board of directors and will depend on, among other things, our results of operations, working capital requirements, capital expenditure requirements, financial condition, level of indebtedness, preferred equity obligations, contractual restrictions with respect to payment of dividends, general economic business conditions, industry practice, business opportunities, anticipated cash needs, provisions of applicable law and other factors that our board of directors may deem relevant. Consequently, your ability to achieve a return on your investment could depend on the appreciation of our Class A common stock. You should not purchase shares of our common stock with the expectation of receiving cash dividends. See “Risk Factors—Risks Relating to this Offering and Ownership of Our Class A Common Stock—We cannot guarantee that we will pay further dividends on our Class A common stock in the future and, consequently, your ability to achieve a return on your investment will depend on appreciation in the price of our Class A common stock.” Further, Delaware law requires that dividends be paid only out of “surplus,” which is defined as the fair market value of our net assets, minus our stated capital; or out of the current or the immediately preceding year’s earnings. In addition, our ability to pay dividends is subject to a range of restrictions and limitations set forth in the instruments governing our indebtedness and preferred equity. For more details, see “Management’s Discussion and Analysis of Financial Condition and Results of Operations—Liquidity and Capital Resources,” “Risk Factors—Risks Related to Our Indebtedness and Financing—Certain of our debt agreements impose significant operating and financial restrictions on our subsidiaries, and the preferred equity of our subsidiaries also gives the holders certain consent rights, all of which may prevent us from capitalizing on business opportunities or paying dividends to the Company” and “Risk Factors—Risks Related to Our Indebtedness and Financing—As a holding company, the Company depends on the ability of its subsidiaries to transfer funds to it to meet its obligations.”

 

101


Table of Contents

CAPITALIZATION

The following table sets forth our cash, cash equivalents and capitalization as of September 30, 2024:

 

   

on an actual basis;

 

   

on a pro forma basis, giving effect to (1) the Stock Split immediately prior to the automatic conversion described in (2); (2) the automatic conversion of all outstanding shares of our Class A common stock held by VG Partners immediately prior to the completion of this offering into shares of our Class B common stock; and (3) the filing and effectiveness of our amended and restated certificate of incorporation, each of which will occur immediately prior to the completion of this offering; and

 

   

on a pro forma as adjusted basis to reflect the sale by us of   shares of Class A common stock in this offering, at an assumed initial public offering price of $   per share, the midpoint of the range set forth on the cover page of this prospectus, after deducting estimated underwriting discounts and commissions and estimated offering expenses, and the application of the net proceeds to us therefrom as described under “Use of Proceeds”.

Each $1.00 increase (decrease) in the public offering price per share would increase (decrease) our cash and cash equivalents, total stockholders’ equity and total capitalization, after deducting estimated underwriting discounts and commissions, by $   million (assuming the number of shares of our Class A common stock offered by us, as set forth on the cover of this prospectus, remains the same, and assuming no exercise of the underwriters’ option to purchase additional shares). We may also increase or decrease the number of shares we are offering. An increase (decrease) of one million shares in the number of shares of our Class A common stock offered by us would increase (decrease) our cash and cash equivalents, total stockholders’ equity and total capitalization, after deducting estimated underwriting discounts and commissions, by $   million (assuming the public offering price remains the same, and assuming no exercise of the underwriters’ option to purchase additional shares).

This table should be read in conjunction with “Use of Proceeds,” “Management’s Discussion and Analysis of Financial Condition and Results of Operations,” “Description of Material Financing” and the audited consolidated financial statements and notes thereto appearing elsewhere in this prospectus.

 

102


Table of Contents
     As of September 30, 2024  
     Actual     Pro Forma      Pro Forma
As Adjusted
 
     (in millions)  
       

Cash and cash equivalents

   $ 4,562     $           $       

Restricted cash, current and noncurrent

     1,073       
  

 

 

   

 

 

    

 

 

 

Total

   $ 5,635     $        $    
  

 

 

   

 

 

    

 

 

 
       

Debt:

       

Project level debt(1)(2)

   $ 16,230     $        $    

VGLNG debt(1)(3)

     11,000       
  

 

 

   

 

 

    

 

 

 

Total debt

     27,230       
  

 

 

   

 

 

    

 

 

 

Redeemable stock of subsidiary(4)

     1,492       

Equity(5):

       

Preferred stock, $0.01 par value per share, 1,000,000 shares authorized actual,    pro forma and pro forma as adjusted, no shares outstanding actual, pro forma and pro forma as adjusted

     —        

Class A common stock, $0.01 par value per share, 1,000,000 shares authorized actual,    shares authorized pro forma and    shares authorized pro forma as adjusted, 519,772 shares outstanding actual,(6)    shares outstanding pro forma and    shares outstanding pro forma as adjusted

     —        

Class B common stock, $0.01 par value per share, 1,000,000 shares authorized actual,    shares authorized pro forma    and    shares authorized pro forma as adjusted, no shares outstanding actual,    shares outstanding pro forma and    shares outstanding pro forma as adjusted

     —        

Additional paid-in capital

     531       

Retained earnings

     1,673       

Accumulated other comprehensive loss

     (252     
  

 

 

   

 

 

    

 

 

 

Total Venture Global, Inc. stockholders’ equity

     1,952       
  

 

 

   

 

 

    

 

 

 

Non-controlling interests(7)

     3,475       
  

 

 

   

 

 

    

 

 

 

Total capitalization

   $ 34,149     $           $       
  

 

 

   

 

 

    

 

 

 

 

(1)

Balances of the VGLNG Senior Secured Notes, the Calcasieu Pass Credit Facilities, the VGCP Senior Secured Notes and the Plaquemines Credit Facilities reflect the full outstanding principal amount of those obligations without reduction for unamortized premiums, discounts and debt issuance costs.

(2)

As of September 30, 2024 we had no available additional borrowing capacity under the senior secured term loan facility of the Calcasieu Pass Credit Facilities and approximately $254 million of letters of credit issued and outstanding thereunder, and we had approximately $301 million of unutilized borrowing capacity under the working capital facility of the Calcasieu Pass Credit Facilities. As of September 30, we had approximately $2.6 billion of undrawn term loan commitments under the Plaquemines Credit Facilities and approximately $1.2 million of letters of credit issued and outstanding thereunder and approximately $919 million undrawn working capital commitments thereunder.

(3)

Consists of the VGLNG Senior Secured Notes.

(4)

Represents third-party interests in the net assets of the Company’s subsidiary, Calcasieu Pass Funding, LLC, resulting from the issuance of redeemable stock, whereby a fund associated with Stonepeak Infrastructure Partners has the right to redeem its interests for cash upon the occurrence of certain events, with a current redemption value as adjusted by the contractually stated distribution amount that is recognized in each reporting period as net income attributable to redeemable stock of subsidiary on the consolidated statements of operations of approximately $1.5 billion as of September 30, 2024. See “Description of Material Financing—Project Equity Financing—Calcasieu Pass Funding, LLC Preferred Units.”

(5)

The actual number of shares of Class A common stock does not give effect to the Stock Split to be effectuated after the effectiveness of the registration statement of which this prospectus forms a part and before the completion of this offering.

(6)

The actual outstanding number of shares of Class A common stock does not give effect to the Stock Split.

 

103


Table of Contents
(7)

Represents third-party interests in the Company’s subsidiary, Calcasieu Pass Holdings, LLC, resulting from the issuance of preferred units to a fund associated with Stonepeak Infrastructure Partners. Such units will be, upon the occurrence of certain conditions, redeemed for an agreed price or converted into common units of Calcasieu Pass Holdings, LLC. See “Description of Material Financing—Project Equity Financing—Calcasieu Pass Holdings, LLC Preferred Units.” Additionally, this includes approximately $3.0 billion in third party interests in VGLNG, resulting from the issuance of three million of VGLNG Series A Preferred Shares. See “Description of Material Financing—VGLNG Equity Financing—VGLNG Series A Preferred Shares.”

 

104


Table of Contents

DILUTION

If you invest in our Class A common stock in this offering, your ownership interest will be diluted immediately to the extent of the difference between the initial public offering price per share of our Class A common stock and the pro forma as adjusted net tangible book value per share of our Class A common stock immediately after this offering.

We have presented dilution in the pro forma as adjusted net tangible book value per share after this offering assuming that the holder of our Class B common stock had all of its Class B common stock converted to newly issued shares of Class A common stock on a one-for-one basis in order to more meaningfully present the dilutive impact to the investors in this offering. We refer to the assumed conversion of all Class B common stock for shares of Class A common stock as described above in the previous sentence as the “Assumed Conversion.”

Our historical net tangible book value as of September 30, 2024 was $   billion, or $   per share of our Class A common stock. Our historical net tangible book value is the amount of our total tangible assets less our total liabilities. Historical net tangible book value per share represents historical net tangible book value, divided by the number of outstanding shares of our Class A common stock.

Our pro forma net tangible book value as of September 30, 2024 was $   billion, or $   per share of Class A common stock. Pro forma net tangible book value per share represents pro forma tangible assets, less pro forma liabilities, divided by the pro forma aggregate number of shares of Class A common stock outstanding, after giving effect to (i) the Stock Split immediately prior to the automatic conversion described in (ii); (ii) the automatic conversion of all outstanding shares of our Class A common stock held by VG Partners immediately prior to the completion of this offering into shares of our Class B common stock; (iii) the filing and effectiveness of our amended and restated certificate of incorporation, each of (i) and (ii) will occur immediately prior to the completion of this offering; and (iv) the Assumed Conversion.

After giving effect to the sale by us of   shares of Class A common stock in this offering, at an assumed initial public offering price of $   per share (the midpoint of the range set forth on the cover page of this prospectus), and the receipt and application of the net proceeds after deducting estimated underwriting discounts and commissions and estimated offering expenses payable by us, our pro forma as adjusted net tangible book value as of September 30, 2024 would have been $   , or $   per share. This represents an immediate increase in pro forma as adjusted net tangible book value to existing stockholders of $   per share and an immediate dilution to new investors of $   per share. Dilution per share represents the difference between the price per share to be paid by new investors for the shares of Class A common stock sold in this offering and the pro forma as adjusted net tangible book value per share immediately after this offering. The following table illustrates this per share dilution:

 

Assumed initial public offering price

      $       

Historical net tangible book value per share as of     

   $          

Pro forma net tangible book value per share as of     

     

Increase in pro forma as adjusted net tangible book value per share attributable to new investors

     
  

 

 

    

Pro forma as adjusted net tangible book value per share after offering

     
     

 

 

 

Dilution per share to new investors

      $       
     

 

 

 

Each $1.00 increase (decrease) in the assumed initial offering price of $   per share of our Class A common stock would increase (decrease) our pro forma as adjusted net tangible book value as of September 30, 2024, after deducting estimated underwriting discounts and commissions, by approximately $   million, or

 

105


Table of Contents

approximately $   per share, and the dilution per share to new investors by approximately $    (assuming (i) the number of shares of our Class A common stock offered by us, as set forth on the cover of this prospectus, remains the same, (ii) no exercise of the underwriters’ option to purchase additional shares and (iii) the Assumed Conversion). We may also increase or decrease the number of shares we are offering. An increase of one million shares in the number of shares offered by us would result in pro forma as adjusted net tangible book value as of September 30, 2024, after deducting estimated underwriting discounts and commissions, of approximately $   million, or $    per share, and the dilution per share to investors in this offering would be $   per share (assuming (i) the public offering price remains the same, (ii) no exercise of the underwriters’ option to purchase additional shares and (iii) the Assumed Conversion). Similarly, a decrease of one million shares in the number of Class A shares of common stock offered by us would result in pro forma as adjusted net tangible book value as of September 30, 2024, after deducting estimated underwriting discounts and commissions, of approximately $   million, or $   per share, and the dilution per share to investors in this offering would be $   per share (assuming (i) the public offering price remains the same, (ii) no exercise of the underwriters’ option to purchase additional shares and (iii) the Assumed Conversion). The information discussed above is illustrative only and will adjust based on the actual public offering price and other terms of this offering determined at pricing.

The following table sets forth, on a pro forma as adjusted basis, as of September 30, 2024, the number of shares of common stock purchased from us, the total consideration paid, or to be paid, and the average price per share paid, or to be paid, by existing stockholders and by the new investors, at an assumed initial public offering price of $   per share (the midpoint of the range set forth on the cover page of this prospectus), before deducting estimated underwriting discounts and commissions and estimated offering expenses payable by us, and gives effect to the Assumed Conversion:

 

     Shares Purchased     Total
Consideration
    Average
Price
Per Share
 
     Number      Percent     Amount      Percent     Amount  

Existing stockholders

              $                    $       

New investors

                             
  

 

 

    

 

 

   

 

 

    

 

 

   

 

 

 

Total

        100     $        100   $       
  

 

 

    

 

 

   

 

 

    

 

 

   

 

 

 

Each $1.00 increase (decrease) in the assumed initial offering price of $   per share of Class A common stock would increase (decrease) the total consideration paid by new investors by approximately $   million, or the percent of total consideration paid by new investors by approximately   % (assuming the number of shares of our Class A common stock offered by us, as set forth on the cover of this prospectus, remains the same, and assuming no exercise of the underwriters’ option to purchase additional shares). We may also increase or decrease the number of shares we are offering. An increase (decrease) of shares in the number of one million shares offered by us would increase (decrease) the total consideration paid by new investors by approximately $   million, or the percent of total consideration paid by new investors by approximately   % (assuming the public offering price remains the same, and assuming no exercise of the underwriters’ option to purchase additional shares).

After giving effect to the sale of shares in this offering, assuming the underwriters’ option to purchase additional shares is not exercised and after giving effect to the Assumed Conversion, our existing stockholders would own approximately   % (or   % if the underwriters’ option is exercised in full) and our new investors would own approximately   % (or   % if the underwriters’ option is exercised in full) of the total number of shares of our Class A common stock outstanding after this offering.

 

106


Table of Contents

The information discussed above is illustrative only and will adjust based on the actual public offering price and other terms of this offering determined at pricing. The foregoing tables assume no exercise of the underwriters’ option to purchase additional shares or of outstanding stock options after September 30, 2024. As of September 30, 2024,   shares of Class A common stock were subject to outstanding options, at a weighted average exercise price of $   , and we expect to make IPO Grants in connection with this offering pursuant to which approximately     shares of Class A common stock will be subject to options with an exercise price per share equal to the initial public offering price. To the extent these options are exercised, there will be further dilution to new investors.

 

107


Table of Contents

MANAGEMENT’S DISCUSSION AND ANALYSIS

OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS

The following discussion and analysis of our financial condition and results of operations should be read together with our consolidated financial statements, our interim condensed consolidated financial statements and the other financial information appearing elsewhere in this prospectus. This discussion contains forward-looking statements that involve risks and uncertainties. Our actual results could differ materially from those anticipated in the forward-looking statements as a result of various factors, including those discussed below and those discussed in the sections entitled “Risk Factors” and “Forward-Looking Statements” included elsewhere in this prospectus.

Overview

Venture Global has fundamentally reshaped the development and construction of liquefied natural gas production, establishing us as a rapidly growing company delivering critical LNG to the world. Our innovative and disruptive approach, which is both scalable and repeatable, allows us to bring LNG to a global market years faster and at a lower cost. We believe supplying this clean, affordable fuel promotes global energy security and is essential to meeting growing global demand.

Natural gas is one of the most important resources worldwide and is required to generate reliable electricity that underpins economic development and drives industry. Once natural gas is supercooled to -260°F, it converts to liquid form and reduces to 1/600th of its original volume, enabling large quantities of natural gas to be loaded and shipped by LNG tankers. The resulting LNG can be transported to international markets that lack domestic supply, displacing more carbon intensive sources of energy such as coal, diesel, and heavy fuel oil, and serving as an integral part of a cleaner energy future. We believe our business model has demonstrated that in a competitive commodity market, lower cost and overall faster delivery wins market share. Our approach capitalizes on both of these advantages, supporting significant additional growth opportunities.

We are commissioning, constructing, and developing five natural gas liquefaction and export projects near the Gulf of Mexico in Louisiana, utilizing our unique “design one, build many” approach. Each project is designed or is being developed to include an LNG facility and associated pipeline systems that interconnect with several interstate and intrastate pipelines to enable the delivery of natural gas into the LNG facility. Our five current projects are being designed to deliver a total expected peak production capacity of 143.8 mtpa, which consists of an aggregate of 104.4 mtpa expected nameplate capacity and an aggregate of 39.4 mtpa of expected excess capacity. These amounts do not account for any potential bolt-on expansion liquefaction capacity.

Fundamentals of Our Business

Revenue from LNG sales

We aim to generate revenue primarily from the sale of LNG produced at our facilities, both during the commissioning of each of our projects and after our projects achieve COD.

Our primary source of revenue has been the sale of commissioning cargos at the Calcasieu Project, and we expect that to continue until at least one of our projects becomes fully operational. Although the construction of the Calcasieu Project is substantially complete, the project is currently undergoing a multi-faceted commissioning program to complete the facility’s components, bring them to design specification and establish reliable and safe facility-wide operating conditions in preparation for the commencement of lender-required performance reliability testing. Significant work related to commissioning, carryover completions, rectification, including remedying unexpected challenges with equipment reliability identified during the first-time implementation of our innovative design and configuration, and reliability testing, is ongoing and we believe will need to be completed before certain components operate as intended and the facility can be fully commercially

 

108


Table of Contents

operable, and COD can occur. As of September 30, 2024, we had received approximately $19.6 billion in gross proceeds (approximately $14.2 billion in net proceeds after deducting net cash paid for natural gas, which primarily includes the net cost of purchasing and transporting feed gas) from such commissioning cargos at the Calcasieu Project. Commissioning cargos are sold to various customers under master SPAs, either as single cargos or as multiple cargos to be loaded over a period of time, and are based on spot and/or forward prices at the time of execution. As a result, the amount of revenue we are able to generate from such sales of commissioning cargos has differed, and will likely continue to differ, from period to period and from project to project, and such differences could be material.

The majority of the nameplate capacity at the Calcasieu Project, Plaquemines Project and Phase 1 of the CP2 Project after they achieve their COD will be sold under long-term 20-year post-COD SPAs, at which point our revenue will primarily depend on the contract prices for the sale of LNG under such post-COD SPAs and the price at which we sell any excess capacity that we produce at our facilities in excess of the relevant nameplate capacity. As of September 30, 2024, we have entered into post-COD SPAs with respect to 39.25 mtpa of the aggregate expected nameplate capacity for our first three projects of 50 mtpa. The post-COD SPAs cover the entire nameplate capacity of the Calcasieu Project, equivalent to 10.0 mtpa, and the entire nameplate capacity of the Plaquemines Project, equivalent to 20.0 mtpa, with the remaining 9.25 mtpa covering approximately 64% of the nameplate capacity of the CP2 Project’s Phase 1, equivalent to 14.4 mtpa. Of the 39.25 mtpa of the aggregate contracted expected nameplate capacity, 37.45 mtpa is contracted under 20-year fixed price post-COD SPAs and 1.8 mtpa is contracted on a short- or medium-term basis. We aim to market and sell the expected nameplate capacity at our subsequent projects (including the CP2 Project, CP3 Project and Delta Project) under a combination of long-term 20-year post-COD SPAs as well as short- and medium-term post-COD SPAs to optimize the average fixed facility charge across our SPAs.

After achieving COD for each of our projects, we intend to market and sell any quantities of LNG that are not contractually committed, including any LNG produced above the relevant project’s nameplate capacity, or excess capacity. Such quantities of LNG are expected to be marketed and sold through VG Commodities, a wholly-owned subsidiary, pursuant to certain intercompany SPAs, providing an opportunity to generate additional revenue on an ongoing basis.

Project costs

We have incurred significant project costs, and we expect to continue to incur significant additional costs, in connection with the development, construction and commissioning of our projects prior to the commencement of commercial operations. Project costs include the engineering, procurement and construction costs, as well as owners’ costs and financing costs related to our projects. For details on the risks relating to the cost estimates presented herein, see “Risk Factors—Risks Relating to Our Projects and Other Assets—Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.” The ultimate project costs that we incur will impact our future depreciation expense and interest expense and, as a result, will impact our future gross and operating margins. Generally, we expect to finance approximately 50% to 75% of the anticipated project costs of each of our projects with project-level debt financing (which may include limited recourse debt), and the remaining 25% to 50% with project-level equity (which may consist of equity contributions by us, equity financing transactions, mezzanine financing and/or other similar financing alternatives). However, the proportion of debt-to-equity funding will depend on various factors, including market conditions and the amount of long-term contracted revenue for the relevant project. We may consider alternative structures to raise capital for those projects and, as a result, there can be no assurance that the financing structure for the CP2 Project, the CP3 Project, the Delta Project or any future project we may develop will be similar to those used for the Calcasieu Project and Plaquemines Project.

 

   

Calcasieu Project. We currently estimate that the total project costs for the Calcasieu Project will be approximately $9.8 billion, including EPC contractor profit and contingency, owners’ costs and financing costs, and we expect that the remaining project costs to achieve the project completion date

 

109


Table of Contents
 

for the Calcasieu Project will be funded with cash held in cash reserve accounts pursuant to our project financing arrangements. Such cash is reflected as restricted cash on our balance sheet as of September 30, 2024, and is in an amount we expect to be sufficient to complete the project and achieve COD for the Calcasieu Project.

 

   

Plaquemines Project. We currently estimate that the total project costs for the Plaquemines Project will be approximately $22 billion to $23 billion, including EPC contractor profit and contingency, owners’ costs and financing costs. Of the total project costs for the Plaquemines Project, approximately $17.7 billion had been paid for as of September 30, 2024. We believe we have sufficient project-level cash, borrowing capacity under our existing project-level debt financing, and access to substantial commissioning cargo proceeds to fund the completion of the Plaquemines Project based on our current estimate of the total project costs.

 

   

CP2 Project. We currently estimate that the total project costs for the CP2 Project will be approximately $27 billion to $28 billion, including EPC contractor profit and contingency, owners’ costs and financing costs. Given that we have not executed certain contracts to construct the CP2 Project, including the EPC contract with respect to Phase 2 of the CP2 Project, this estimate is based upon the contracts that we have in place for the CP2 Project and our construction cost experiences with the Calcasieu Project and the Plaquemines Project. The cost estimates for the CP2 Project reflect the current inflationary environment, and may be higher, potentially materially, compared to our current estimates as a result of many factors. In addition, we expect to construct longer pipelines for the CP2 Project than for the Calcasieu Project and the Plaquemines Project. We have not yet raised project-level debt or equity financing for the CP2 Project.

 

   

CP3 Project and Delta Project. We currently estimate that the total project costs for the CP3 Project and the Delta Project will be approximately $44 billion to $45 billion and $37 billion to $38 billion respectively, in each case including EPC contractor profit and contingency, owners’ costs and financing costs. Given that we have not executed EPC contracts with respect to any portion of the CP3 Project or the Delta Project, and that no substantial construction work has been undertaken on either of those projects to date, these estimates are based upon our construction cost experiences with the Calcasieu Project, the Plaquemines Project and the contracts that we have executed for the CP2 Project. The cost estimates for the CP3 Project and the Delta Project reflect the current inflationary environment, and may be higher, potentially materially, compared to our current estimates as a result of many factors. In addition, we expect to construct longer pipelines for the CP3 Project and the Delta Project than for the Calcasieu Project and the Plaquemines Project. Furthermore, our cost estimates might change due to factors such as unexpected delays in the construction or commissioning of our projects, the execution of any repair or warranty work and change orders or amendments to certain material construction contracts, including final terms of or amendments to any EPC contract for such projects, and/or other construction or supply contracts. We have not yet raised project-level debt or equity financing for the CP3 Project or the Delta Project.

Reorganization Transactions and Historical Financial Statements

In September 2023, we engaged in a series of reorganization transactions, or the Reorganization Transactions, that ultimately resulted in the Company becoming the principal parent company of our entire enterprise. See “Certain Relationships and Related Party Transactions—Reorganization Transactions” for further information. As a result of the Reorganization Transactions, effective as of September 25, 2023, VGLNG, our principal operating company, became a direct, wholly-owned subsidiary of the Company. Additionally, effective as of September 25, 2023, VG Commodities, formerly a wholly-owned subsidiary of Legacy VG Partners, became a wholly-owned subsidiary of the Company and a direct, wholly-owned subsidiary of VGLNG.

The Reorganization Transactions were accounted for as a common control transaction, prior to which the Company had no operations and no assets or liabilities. Accordingly, the financial results and other information

 

110


Table of Contents

included in the Company’s consolidated financial statements and presented in this prospectus for periods prior to consummation of the Reorganization Transactions are reflective of Legacy VG Partners, except for earnings per share, which has been recast to reflect the impact of VGLNG’s historical outstanding shares as if they had been the shares of the Company converted in a one-for-one-exchange. See “Note 1 – The Company” in our annual financial statements included elsewhere in this prospectus for further information.

Key Factors Affecting Results of Operations

The key factors affecting our results of operations and financial performance are as follows:

Sales of LNG during commissioning of our projects. We aim to generate cash proceeds from the sale of LNG produced during the commissioning phase of each of our projects. Our ability to generate such cash proceeds, and the amount of any such cash proceeds, will depend primarily on the duration of the commissioning phase for each of our projects, the volume of LNG that we are able to produce during the commissioning phase, our ability to negotiate sales of LNG produced during the commissioning phase, as well as the market price for LNG at the time of such sales. As a result, the amount of cash proceeds we are able to generate from such sales of commissioning cargos will likely differ from period to period and from project to project, and such differences could be material.

Sales of LNG post-COD of our projects. We aim to generate cash proceeds from the sale of LNG produced after COD for each of our projects under a combination of long-term 20-year post-COD SPAs as well as short- and medium-term post-COD SPAs to optimize the average fixed facility charge across our SPAs. Further, to the extent our projects generate excess capacity relative to the nameplate capacity, we expect to sell such excess capacity as described below. None of our projects have achieved COD as of the date of this prospectus. Our ability to generate cash proceeds from such sales, and the amount of any such cash proceeds that we are able to generate, will be contingent upon achieving COD at each of our projects, and will vary depending on the following key factors:

 

   

Contract price under our SPAs. Our existing post-COD SPAs will require our export customers to pay us a fixed facility charge per MMBtu, plus a variable commodity charge per MMBtu, in an amount equal to, depending on the applicable SPA, 115% or more of the Henry Hub gas price. The fixed facility charge varies across our post-COD SPAs and a portion of the fixed facility charge will be adjusted for inflation. For any additional post-COD SPAs that we may enter into in the future which include a fixed facility charge, that amount will be based on several factors, including market conditions at the time we enter into the relevant contract. Final terms for any additional post-COD SPAs we may enter into in the future will not be known until those contracts are executed and will impact our future revenue, as well as our operating margins.

 

   

Henry Hub gas price. As described above, the variable commodity charge under our post-COD SPAs requires our customers to pay 115% or more of the Henry Hub gas price per MMBtu, which is intended to cover the price of the feed gas and gas transportation costs, and is also intended to cover certain of our operating expenses and partially adjust for inflation. We anticipate that any additional post-COD SPAs we enter into in the future will similarly require our export customers to pay a similar variable commodity charge. As a result, changes in the Henry Hub gas price will impact our future revenue, as well as our operating margins. In addition, there may be differences, and such differences may be material, between the actual price we pay for feed gas and the Henry Hub gas price used to calculate the variable commodity charges payable by our customers under the relevant post-COD SPAs, which could affect our operating margins.

 

   

Sales of uncommitted and excess LNG. We intend to market and sell any uncommitted LNG and any excess capacity through VG Commodities, providing the flexibility to optimize pricing for such sales. Our ability to generate cash proceeds from such sales, and the amount of any such cash proceeds that we are able to generate, will depend primarily on the volume of LNG that has been contracted under post-COD SPAs and the amount of LNG that we are able to produce at any project in excess of the

 

111


Table of Contents
 

nameplate capacity, our ability to negotiate sales of such uncommitted and excess LNG, as well as the market price for LNG at the time of such sales or the terms of any SPA we are able to negotiate with respect to such sales. As a result, the amount of cash proceeds we are able to generate from such sales of uncommitted and excess LNG, if any, will likely differ from period to period and from project to project, and such differences could be material.

Cost of feed gas. The direct costs of purchasing, transporting and converting natural gas to LNG for sale to our customers are the main component of our cost of sales. Under the post-COD SPAs and substantially all of the commissioning cargo sales that we have executed to date, our export customers pay a fixed facility charge (which includes a CPI-linked component) per MMBtu, plus a variable commodity charge per MMBtu, in an amount equal to, depending on the applicable SPA, 115% or more of the Henry Hub gas price, which is intended to cover the price of the feed gas and gas transportation costs, and is also intended to cover certain of our operating expenses and partially adjust for inflation. If we are successful in producing and selling excess LNG produced by our projects, we expect our cost of sales to increase as we will be required to purchase more feed gas to produce more LNG.

Project costs and expenses. We currently have five projects in various stages of development. We expect our development, construction and commissioning expenses for any particular project to increase significantly as we approach and commence the construction phase, and we expect these expenses will continue to be significant until the commissioning phase has been completed and the relevant project reaches its COD. Moreover, our project costs may be higher than we currently estimate due to many factors outside of our control, which could lead to higher development, construction and commissioning expenses for our projects. In addition, we expect to increase our project-dedicated staff as we progress towards the commencement of construction of the CP2 Project, CP3 Project and Delta Project and when we subsequently commence operation at our facilities. As a result, we anticipate that operating and maintenance expenses will increase significantly as we approach commissioning and operation of our projects (as was the case for the Calcasieu Project). We outsource certain major equipment maintenance activities under long-terms service arrangements, but our various operating subsidiaries are responsible for performing day-to-day operations and maintenance work for our projects. See “Business—Major Consultants and Contractors” for more information. Once one of our projects has commenced full commercial operations, we anticipate that the timing of the operating and maintenance costs under the long-term service arrangements for that project will be relatively predictable, subject to inflation, and will generally increase during periods in which regularly scheduled or other maintenance is performed. Increases in operating and maintenance expenses would impact our operating margins. Further, we anticipate that insurance premiums for LNG projects may increase due to losses and claims that have arisen or been experienced in respect of other unrelated projects in other regions, or losses and claims that are large enough to impact the broader insurance market even if an LNG project is not involved.

Effective tax rates and regulations. We utilize various tax incentive programs the State of Louisiana offers, including the industrial tax exemption, to offset local and state taxes that would otherwise be payable. However, the industrial tax exemption will expire after two 5-year periods, which would begin on the last day of the tax year in which the Calcasieu Project, the Plaquemines Project and the CP2 Project assets, as applicable, are placed in service from an accounting perspective, and afterwards ad valorem taxes may be levied against our properties. We anticipate similar tax exemptions will be available for the CP3 Project and Delta Project, although any such exemptions may only be available at lower rates. The future rates at which any taxes (including ad valorem taxes, inventory taxes, franchise taxes and utility taxes) will be levied against us will impact our operating margins.

Inflation. Inflation remains a variable factor in the United States economy, and it may impact our operating margins and results of operations in the future. In particular, we anticipate that the post-COD SPAs that include a fixed facility charge and that we enter into will only be partially adjusted for inflation over the contract term, as is the case with our existing post-COD SPAs as described above. In addition, we anticipate that our operating costs will experience inflationary pressure over time, and the commodity charge we charge our customers for

 

112


Table of Contents

recovery of these costs is based on the price of natural gas per MMBtu. We also expect to experience inflation with respect to the cost of equipment and personnel necessary to develop, construct and operate our projects. See “Risk Factors—Risks Relating to Our Projects and Other Assets—Our estimated costs for our projects have been, and continue to be, subject to change due to various factors” and “Risk Factors—Risks Relating to Our Business—We and our contractors, including our EPC contractors, may experience increased labor costs, and the unavailability of skilled workers or our failure to attract and retain qualified personnel could adversely affect us.”

Seasonality. Seasonal weather can affect demand for LNG and accordingly can impact our ability to sell LNG during the commissioning of our facilities or once our facilities achieve their respective CODs. We have already begun experiencing, and we expect to experience for our other projects, the effects of market volatility and fluctuation in seasonal demand for LNG in our existing markets. For example, temperature and weather in the markets we supply, as well as the amount of natural gas in storage in such markets, may affect both power demand and power generation mix, including the portion of electricity provided through other sources of energy, such as hydroelectric, solar or wind, thus affecting the need for LNG. Further, slower-than-expected inventory withdrawal due to mild weather can decrease the demand for LNG. Other factors, including but not limited to the price spread between European and Asian LNG indices and the availability of LNG tankers and the routes they choose to take due to seasonal and other factors can also affect the price of LNG. As a result, our ability to generate cash proceeds from LNG sales on a spot basis, and to enter into new SPAs for the sale of LNG, may be impacted by such factors, which may in turn result in fluctuations in revenue during quarters of high and low demand, respectively, and could have a disproportionate effect on our results of operations. As such, our results of operations across different fiscal quarters may not be comparable or accurate indicators of our future performance. For more information on these risks, see “Risk Factors—Risks Relating to Our Business—Seasonal fluctuations will cause our business and results of operations to vary among quarters, which could adversely affect our business and results of operations, which could, in turn, negatively affect the price of our Class A common stock.”

Macroeconomic Trends. Macroeconomic conditions, such as high inflation and elevated interest rates, continue to be sources of volatility and uncertainty for global economic activity, and may affect our project costs and operations, as discussed above. See “Risk Factors—Risks Relating to Our Business—Our ability to maintain profitability and positive operating cash flows is subject to significant uncertainty.” Ongoing geopolitical conflicts in Ukraine, the Middle East, and tensions in United States-China relations may drive further economic instability and inflationary pressures, as well as increase risks for the global flow of goods, including energy. In the case of the LNG market, these geopolitical conflicts have and may continue to impact the availability of materials required for the development of LNG projects, in addition to disrupting the supply of LNG, resulting in price volatility on non-SPA volumes. For additional information on historical net spread volatility see “Risk Factors—Risks Relating to Our Business—Our ability to generate proceeds from sales of commissioning cargos is subject to significant uncertainty and volatility in such proceeds. Historical proceeds from such sales at the Calcasieu Project, which has had an extended commissioning period due to unanticipated challenges with equipment reliability that we are in the process of remediating, may not be indicative of the duration of the commissioning period or the amount of proceeds for any future period or for any of our other projects.”

Financial Operations Overview

Revenue

We have a limited operational history. Although we began generating proceeds from sales of commissioning cargos at the Calcasieu Project in the first quarter of 2022, we did not commence recognizing sales of LNG as revenue in our financial statements until April 2022, with the assets of the Calcasieu Project being placed in service from an accounting perspective between April and August of 2022.

At the Calcasieu Project, significant work related to commissioning, carryover completions, and rectification is currently ongoing and includes remedying unexpected challenges with equipment reliability

 

113


Table of Contents

identified during the first-time implementation of our innovative design and configuration, and reliability testing. We believe such work will need to be completed before certain components operate as intended and the facility can be fully commercially operable, and COD can occur. Given such ongoing work, we are targeting to complete all remediation work and achieve COD in the end of March 2025 once the project has completed its commissioning process and testing and is capable of safely and reliably producing its designed nameplate levels of LNG volumes. At such time, we expect to commence LNG deliveries under our post-COD SPAs relating to the Calcasieu Project.

We aim to commence production at each of our projects on a sequential basis, with each liquefaction train being brought online as it is commissioned.

We recognize revenue when we transfer control of promised goods or services to our customers, in an amount that reflects the consideration we expect to receive in exchange for those goods or services. Revenue from the sale of LNG is recognized at the point in time when the LNG is delivered to the customer at the agreed upon LNG terminal, which is the point when legal title, physical possession and the risks and rewards of ownership transfer to the customer. Each individual molecule of LNG is viewed as a separate performance obligation. The stated contract price, including both fixed and variable components, is representative of the stand-alone selling price for LNG at the time the contract was negotiated.

Generally, we recognize sales of LNG as revenue in our financial statements. However, when we produce LNG at our projects prior to the assets of that project being placed in service from an accounting perspective, we recognize the net proceeds from the generation and sale of that LNG as a reduction to the cost basis of construction in progress, in accordance with the applicable accounting guidance. In our financial statements, we refer to the LNG produced at our facilities before such assets are placed in service from an accounting perspective as test LNG and the proceeds from their sale as test LNG sales. For the Calcasieu Project, the assets were placed in service from an accounting perspective between April and August 2022. The proceeds from test LNG sales are determined based on estimates of LNG production generated from commissioning activities. The production and sale of test LNG during this period are activities necessary to get the facility ready for its intended use. Test LNG sales are recognized as a reduction to the cost basis of construction and the cost of producing test LNG is recognized as an addition to the cost basis of construction. Once assets are placed in service from an accounting perspective, we then begin recognizing the sales of LNG as revenue in our financial statements.

Operating Expenses

Our operating expenses consist primarily of cost of sales, operating and maintenance expenses, general and administrative expenses, development expenses, and depreciation and amortization.

Cost of Sales

Cost of sales is comprised of the direct cost of producing LNG recognized as revenue. It includes the cost of purchasing and transporting natural gas used to produce LNG, also known as feed gas, and excludes depreciation and amortization shown separately on the consolidated statements of operations.

Under our existing post-COD SPAs and under substantially all of the commissioning cargo sales that have been executed to date, our export customers pay a fixed facility charge (which includes a CPI-linked component) per MMBtu, plus a variable commodity charge per MMBtu, in an amount equal to, depending on the applicable SPA, 115% or more of the Henry Hub gas price, which is intended to cover the price of the feed gas and gas transportation costs, and is also intended to cover certain of our operating expenses and partially adjust for inflation.

 

114


Table of Contents

Operating and Maintenance Expenses

Operating and maintenance expenses primarily include non-capitalizable costs directly associated with the operation and maintenance of our projects, including personnel costs, the cost of spares and consumables used in maintenance, land lease expense, Asset Retirement Obligation, or ARO, accretion expense, and project-related information technology costs and contractors. We outsource certain major equipment maintenance activities, but our various operating subsidiaries are responsible for performing day-to-day operations and maintenance work for our projects. See “Business—Major Consultants and Contractors” for more information. We anticipate that operating and maintenance expenses will increase significantly as we transition to the commissioning and operation of our projects (as was the case for the Calcasieu Project).

General and Administrative Expenses

General and administrative expenses consist primarily of costs not directly associated with the operations or development of our projects such as our corporate functions including executive management, information technology (except for direct project-related IT costs that are included in operating and maintenance expense), human resources, legal and finance. In addition, we expect that after the completion of this offering, we will incur additional personnel, audit, tax, accounting, legal and other costs related to compliance with applicable securities laws and other regulations, as well as additional insurance, investor relations and other costs associated with being a public company.

Development Expenses

Development expenses consist primarily of costs incurred to develop a project prior to management’s conclusion that construction and completion of that project is probable and that are not otherwise recoverable in other projects or for resale as well as construction stage costs that are not capitalizable. These expenses consist primarily of engineering and design expenses and other development related expenses to the extent these costs cannot be capitalized.

The costs incurred to develop our LNG projects are generally treated as development expenses until construction and completion of the relevant project is considered probable by our management. After an LNG project is deemed probable, the costs associated with the development and construction of the liquefaction facility and associated pipeline, including capitalized interest, are recorded as construction in progress, and not an operating expense. In assessing probability, we consider whether: (i) management has committed to funding construction of the LNG project, (ii) financing for the project is available, (iii) the ability exists to meet the necessary local and other governmental regulations, (iv) SPAs with respect to an adequate amount of the expected nameplate capacity of the project have been entered into, and (v) equipment and construction contracts for the project have been secured. In October 2018, we met these criteria with respect to the Calcasieu Project and costs associated with the development and construction of the liquefaction facility and associated pipeline, including capitalized interest, have been recorded on our balance sheet as construction in progress since that date. On March 1, 2022 and June 30, 2022, we met these criteria with respect to Phase 1 and Phase 2 of the Plaquemines Project, respectively, and costs associated with the development and construction of the liquefaction facility and associated pipeline, including capitalized interest, have been recognized on our balance sheet as construction in progress or advanced equipment payments to the extent allowed under the applicable accounting guidance since that date. As of September 30, 2024, we had not met these criteria with respect to the CP2 Project, the CP3 Project, or the Delta Project. The costs incurred to date related to these projects have been capitalized to the extent allowable under GAAP, otherwise they have been, and will continue to be, expensed until such conditions are met. We have capitalized the cost of equipment and materials that are expected to be used on projects that are not yet probable when the equipment and materials have alternative use and are otherwise recoverable in other projects or for resale. Additionally, we have capitalized payments to landowners for rights-of-way along the proposed pipeline routes, certain leasehold improvement costs necessary for preparing the facilities for their intended use and direct costs of construction-related activities incurred with third parties,

 

115


Table of Contents

including, but not limited to, payments for certain detailed engineering design work and the early procurement of certain long lead-time equipment to the extent allowable under the applicable accounting guidance.

Depreciation and Amortization Expense

Beginning in 2022, with the commencement of operations at the Calcasieu Project, we began to incur depreciation for the property, plant and equipment associated with the assets held by the Calcasieu Project over their estimated useful lives. Prior to 2022, depreciation and amortization had been limited to office equipment and furniture, as well as leasehold improvements to our office spaces and certain marine offloading facilities situated on land we have leased near the Calcasieu Project site land. In the future, as new facilities come online, we expect that our depreciation and amortization expense will increase substantially when these assets are placed in service from an accounting perspective.

Interest Income

Interest income consists primarily of interest income earned on our cash and cash equivalents and investments balances. Our cash and cash equivalents and investments are currently held primarily in cash deposits at federally licensed banks, or short-term, investment-grade, interest-bearing instruments and U.S. government securities. We expect our interest income to fluctuate in the future with changes in average investment balances and market interest rates.

Interest Expense

Interest expense consists primarily of financing fees, interest cost, and commitment fees incurred in connection with our various debt financing transactions, partially offset by capitalized interest. See “—Liquidity and Capital Resources.”

We anticipate entering into one or more sources of debt and equity financing to fund certain costs for the CP2 Project, the CP3 Project, the Delta Project, our pipeline development projects, and our LNG tankers. We expect to incur significant additional financing fees and interest expense in connection with the anticipated debt financing related to such LNG projects, pipeline projects, and tankers. Depending on the timing of the financing, we anticipate capitalizing a portion of the interest costs that we incur while the relevant natural gas liquefaction and export facilities, pipeline projects and LNG tankers are under construction. We generally hedge a substantial portion of our outstanding variable rate debt through the use of interest rate swaps that are marked to market. As of December 31, 2023, we had entered into interest rate swaps targeting a hedge ratio of 97% and 80% of our variable rate debt for the Calcasieu Project and the Plaquemines Project, respectively.

Income Tax Expense

We are a corporation organized in Delaware and, as such, are subject to taxation in the United States. See below for a discussion of income tax expense for the periods presented.

During the year ended December 31, 2022, we determined that sufficient positive evidence existed to support recoverability of our federal deferred tax assets and accordingly released the valuation allowance against our federal deferred tax assets. We continued to maintain a valuation allowance against a portion of our state deferred tax assets, for which we continue to believe the more-likely-than-not recognition threshold has not been met. As of December 31, 2023, we have accumulated federal net operating loss carryforwards of $367 million with an indefinite carryforward period. We additionally had accumulated state net operating loss carryforwards of approximately $1.7 billion (after the application of state apportionment factors), of which $42 million will expire by 2037.

 

116


Table of Contents

Segments

We have three reportable segments, which consist of the Calcasieu Pass Project, the Plaquemines Project, and the CP2 LNG Project. Each reportable segment includes activity of both the respective liquefaction and export terminal and the associated pipeline that will supply the natural gas to that facility. Activities relating to certain development stage projects and our shipping business, overhead costs not directly associated with our LNG projects (for example, general and administrative and marketing expenses) and inter-segment eliminations are not material at this time and therefore are included in Corporate, other and eliminations.

Our performance is evaluated based on income (loss) from operations. All revenue and the majority of our long-lived assets were attributed to or located in the United States. Certain assets related to our shipping and marketing activities are located outside of the United States.

We loaded our first export cargo from the Calcasieu Project in March 2022. During the years ended December 31, 2023, and 2022, we loaded 144 and 94 cargos, respectively, and received $7.8 billion and $8.2 billion in gross proceeds, respectively, from such sales (or $6.0 billion and $5.6 billion, respectively, in net proceeds after deducting net cash paid for natural gas, which primarily includes the net cost of purchasing and transporting feed gas). During the nine months ended September 30, 2024 and 2023, we loaded 104 and 103 cargos, respectively, and received $3.6 billion and $6.3 billion in gross proceeds, respectively, from such sales (or $2.6 billion and $4.9 billion, respectively, in net proceeds after deducting net cash paid for natural gas, which primarily includes the net cost of purchasing and transporting feed gas).

Results of Operations

Three Months Ended September 30, 2024 compared to Three Months Ended September 30, 2023

The following table shows a summary of our results of operations for the periods indicated.

 

     Three months ended
September 30,
    Change  
      2024       2023      ($)     (%)  
     ($ in millions)  

Revenue

   $ 926     $ 1,054     $ (128     (12 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Operating Expense:

        

Cost of sales (exclusive of depreciation and amortization shown separately below)

     272       350       (78     (22 )% 

Operating and maintenance expense

     143       126       17       13

General and administrative expense

     77       58       19       33

Development expense

     156       142       14       10

Depreciation and amortization

     89       69       20       29
  

 

 

   

 

 

   

 

 

   

 

 

 

Total operating expense

     737       745       (8     (1 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Income from Operations

     189       309       (120     (39 )% 

Other Income (Expense)

        

Interest income

     53       44       9       20

Interest expense, net

     (128     (154     26       (17 )% 

Gain (loss) on derivatives

     (480     788       (1,268     (161 )% 

Loss on financing transactions

     (6     (3     (3     100
  

 

 

   

 

 

   

 

 

   

 

 

 

Total other income (expense)

     (561     675       (1,236     (183 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Income (loss) before Income Tax Expense (benefit)

     (372     984       (1,356     (138 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Income tax expense (benefit)

     (78     203       (281     (138 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Net Income (loss)

   $ (294   $ 781     $ (1,075     (138 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

 

117


Table of Contents

Revenue

Revenue was $926 million for the three months ended September 30, 2024, a $128 million, or 12%, decrease from $1.1 billion during the three months ended September 30, 2023. This decrease was primarily due to lower LNG sales volumes of commissioning cargos of $147 million mainly resulting from three LNG cargos sold on a delivered basis (at the receiving customer’s terminal) and in transit at September 30, 2024, partially offset by higher net LNG sales prices of $18 million.

Operating Expense

Operating expense was $737 million for the three months ended September 30, 2024, a $8 million, or 1%, decrease from $745 million during the three months ended September 30, 2023. This decrease was primarily the result of a decrease in cost of sales partially offset by an increase in operating and maintenance expense, an increase in depreciation and amortization, and an increase general and administrative expense as discussed below.

Cost of Sales

Cost of sales was $272 million for the three months ended September 30, 2024, a $78 million, or 22%, decrease from $350 million during the three months ended September 30, 2023. This decrease was primarily due to the combined impact of a decrease in LNG sales volumes of $46 million and a decrease in the net cost of natural gas and improved plant efficiency of $35 million.

Operating and Maintenance Expense

Operating and maintenance expense was $143 million for the three months ended September 30, 2024, a $17 million, or 13%, increase from $126 million during the three months ended September 30, 2023. This increase was primarily due to higher costs related to the operation and management of our LNG tankers and higher legal costs at the Calcasieu Project, partially offset by lower operating costs at the Plaquemines Project mainly resulting from a decrease in non-capitalizable personnel costs, partially offset by an increase in ARO accretion expense.

General and Administrative Expense

General and administrative expense was $77 million for the three months ended September 30, 2024, a $19 million, or 33%, increase from $58 million during the three months ended September 30, 2023. This increase was primarily due to higher personnel costs due to an increase in employee headcount and increased sponsorship activities.

Development Expense

Development expense was $156 million for the three months ended September 30, 2024, a $14 million, or 10%, increase from $142 million during the three months ended September 30, 2023. This increase was primarily due to higher engineering and environmental costs at Corporate, and higher lease costs for the CP2 Project, partially offset by a decrease in engineering and environmental costs for the CP2 Project.

Depreciation and Amortization Expense

Depreciation and amortization expense was $89 million for the three months ended September 30, 2024, a $20 million, or 29%, increase from $69 million during the three months ended September 30, 2023. This increase was primarily due to adjustments to the cost basis of certain assets during the three months ended September 30, 2024.

 

118


Table of Contents

Income from Operations

Income from operations was $189 million for the three months ended September 30, 2024, a $120 million, or 39%, decrease from $309 million during the three months ended September 30, 2023. This decrease was primarily the result of lower revenue, partially offset by lower cost of sales, from the sale of LNG produced by the Calcasieu Pass Project, as discussed above. In addition, there was an increase in operating and maintenance expense, an increase in depreciation and amortization, and an increase in general and administrative expense as discussed above.

Other Income (Expense)

Other expense was $561 million for the three months ended September 30, 2024, a $1.2 billion, or 183%, decrease from other income of $675 million during the three months ended September 30, 2023. This decrease from other income was primarily the result of a loss on derivatives during the three months ended September 30, 2024, as compared to a gain during the same period in 2023.

Interest Income

Interest income was $53 million during the three months ended September 30, 2024, a $9 million, or 20%, increase from $44 million during the three months ended September 30, 2023. This increase was primarily due to higher average cash balances and interest rates at Corporate and higher average cash balances at the Plaquemines Project, partially offset by lower average cash balances at the Calcasieu Project during the three months ended September 30, 2024, compared to the same period in 2023.

Interest Expense, Net

Interest expense, net was $128 million during the three months ended September 30, 2024, a $26 million, or 17%, decrease from $154 million during the three months ended September 30, 2023. This decrease was primarily due to lower non-capitalizable interest costs at Corporate and lower commitment fees primarily at the Plaquemines Project.

Gain (Loss) on Derivatives

Loss on derivatives was $480 million for the three months ended September 30, 2024, a $1.3 billion, or 161%, decrease from a gain on derivatives of $788 million during the three months ended September 30, 2023. This decrease was primarily due to a loss on interest rate swaps at the Plaquemines Project of $460 million and at the Calcasieu Project of $20 million during the three months ended September 30, 2024, as a result of decreases in interest rates, as compared to a gain on interest rate swaps at the Plaquemines Project of $769 million and at the Calcasieu Project of $19 million during the three months ended September 30, 2023, as a result of increases in interest rates.

Loss on Financing Transactions

Loss on financing transactions was $6 million for the three months ended September 30, 2024, a $3 million, or 100%, increase from $3 million during the three months ended September 30, 2023. This increase was primarily due to the write-off of debt issuance costs associated with the full prepayment of the equity bridge credit facilities for the Plaquemines Project, or the Plaquemines Equity Bridge Facility, during the three months ended September 30, 2024, as compared to the write-off of debt issuance costs associated with the partial prepayment of the Plaquemines Equity Bridge Facility and a gain recognized on the settlement of agreements to repurchase VGLNG treasury stock during the three months ended September 30, 2023.

Income (Loss) before Income Tax Expense

Loss before income tax expense was $372 million for the three months ended September 30, 2024, a $1.4 billion, or 138%, decrease from $984 million in income before income tax expense during the three months

 

119


Table of Contents

ended September 30, 2023. This decrease in income before income tax expense was primarily the result of a change from gain on derivatives to loss on derivatives and a decrease in our income from operations, as discussed above.

Income Tax Expense (Benefit)

Income tax benefit was $78 million for the three months ended September 30, 2024, a $281 million, or 138%, decrease from income tax expense of $203 million during the three months ended September 30, 2023, driven by a decrease in taxable income. Our effective tax rate was 21.0% for the three months ended September 30, 2024, as compared to 20.6% during the same period in 2023.

Net Income (Loss)

Net loss was $294 million for the three months ended September 30, 2024, a $1.1 billion, or 138%, decrease from net income of $781 million during the three months ended September 30, 2023. This decrease was primarily the result of a change from gain on derivatives to loss on derivatives and a decrease in our income from operations, partially offset by a change from income tax expense to income tax benefit, as discussed above.

Nine Months Ended September 30, 2024 compared to Nine Months Ended September 30, 2023

The following table shows summary of our results of operations for the periods indicated.

 

     Nine months ended
September 30,
    Change  
     2024     2023     ($)     (%)  
     ($ in millions)  

Revenue

   $ 3,448     $ 6,265     $ (2,817     (45 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Operating Expense:

        

Cost of sales (exclusive of depreciation and amortization shown separately below)

     937       1,195       (258     (22 )% 

Operating and maintenance expense

     378       279       99       35

General and administrative expense

     224       165       59       36

Development expense

     511       324       187       58

Depreciation and amortization

     229       208       21       10

Insurance recoveries, net

     —        (19     19       (100 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Total operating expense

     2,279       2,152       127       6
  

 

 

   

 

 

   

 

 

   

 

 

 

Income from Operations

     1,169       4,113       (2,944     (72 )% 

Other Income (Expense)

        

Interest income

     187       103       84       82

Interest expense, net

     (467     (448     (19     4

Gain on derivatives

     70       830       (760     (92 )% 

Loss on financing transactions

     (14     (113     99       (88 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Total other income (expense)

     (224     372       (596     (160 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Income before Income Tax Expense

     945       4,485       (3,540     (79 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Income tax expense

     189       868       (679     (78 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Net Income

   $ 756     $ 3,617     $ (2,861     (79 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

 

120


Table of Contents

Revenue

Revenue was $3.4 billion for the nine months ended September 30, 2024, a $2.8 billion, or 45%, decrease from $6.3 billion during the nine months ended September 30, 2023. This decrease was primarily due to lower LNG sales prices for the sale of commissioning cargos of $3.2 billion, partially offset by higher LNG sales volumes of $406 million.

Operating Expense

Operating expense was $2.3 billion for the nine months ended September 30, 2024, a $127 million, or 6%, increase from $2.2 billion during the nine months ended September 30, 2023. This increase was primarily the result of an increase in development expense, operating and maintenance expense and general and administrative expense. These increases were partially offset by a decrease in cost of sales, as discussed below.

Cost of Sales

Cost of sales was $937 million for the nine months ended September 30, 2024, a $258 million, or 22%, decrease from $1.2 billion during the nine months ended September 30, 2023. This decrease was primarily due to the combined impact of a decrease in the net cost of natural gas and improved plant efficiency of $293 million, partially offset by an increase in LNG sales volumes of $36 million.

Operating and Maintenance Expense

Operating and maintenance expense was $378 million for the nine months ended September 30, 2024, a $99 million, or 35%, increase from $279 million during the nine months ended September 30, 2023. This increase was primarily due to higher operating costs at the Calcasieu Project to support ongoing commissioning and remediation work and higher legal costs, an increase in costs related to the operation and management of our LNG tankers, and higher operating costs in support of the Plaquemines Project mainly resulting from an increase in ARO accretion and non-capitalizable personnel costs.

General and Administrative Expense

General and administrative expense was $224 million for the nine months ended September 30, 2024, a $59 million, or 36%, increase from $165 million during the nine months ended September 30, 2023. This increase was primarily due to higher personnel costs due to an increase in employee headcount, increased sponsorship activities, and our entry into the Venture Global Management Services Agreement (as defined in “Certain Relationships and Related Party Transactions—Management Services Agreements—Venture Global Management Services Agreement”) with VG Partners at the end of the third quarter of 2023.

Development Expense

Development expense was $511 million for the nine months ended September 30, 2024, a $187 million, or 58%, increase from $324 million during the nine months ended September 30, 2023. This increase was primarily due to higher development costs for engineering, environmental services and lease costs related to the CP2 Project and other development projects, partially offset by a decrease in legal costs related to contractor disputes at the Calcasieu Project.

Depreciation and Amortization Expense

Depreciation and amortization expense was $229 million for the nine months ended September 30, 2024, a $21 million, or 10%, increase from $208 million during the nine months ended September 30, 2023. This increase was primarily due to adjustments to the cost basis of certain assets during the nine months ended September 30, 2024.

 

121


Table of Contents

Insurance Recoveries, Net

Insurance recoveries, net were $19 million for the nine months ended September 30, 2023, due to the recognition of the Company’s portion of insurance claims received in connection with Hurricane Laura. There was no similar activity during the nine months ended September 30, 2024.

Income from Operations

Income from operations was $1.2 billion for the nine months ended September 30, 2024, a $2.9 billion, or 72%, decrease from $4.1 billion during the nine months ended September 30, 2023. This decrease was primarily the result of lower revenue, partially offset by lower cost of sales, from the sale of LNG produced by the Calcasieu Project, as discussed above. In addition, there were increases in development expense, operating and maintenance expense, and general and administrative expense, as discussed above.

Other Income (Expense)

Other expense was $224 million for the nine months ended September 30, 2024, a $596 million, or 160%, decrease from other income of $372 million during the nine months ended September 30, 2023. This decrease from other income was primarily the result of a decrease in gain on derivatives. This decrease in other income (expense) was partially offset by a decrease in loss on financing transactions and an increase in interest income, as discussed below.

Interest Income

Interest income was $187 million during the nine months ended September 30, 2024, an $84 million, or 82%, increase from $103 million during the nine months ended September 30, 2023. This increase was primarily due to higher average cash balances and interest rates at Corporate during the nine months ended September 30, 2024, compared to the same period in 2023.

Interest Expense, Net

Interest expense, net was $467 million during the nine months ended September 30, 2024, a $19 million, or 4%, increase from $448 million during the nine months ended September 30, 2023. This increase was primarily due to higher non-capitalizable interest costs at Corporate, partially offset by lower commitment fees primarily at the Plaquemines Project.

Gain on Derivatives

Gain on derivatives was $70 million for the nine months ended September 30, 2024, a $760 million, or 92%, decrease from $830 million during the nine months ended September 30, 2023. This decrease was primarily due to a decrease in the gain on the Plaquemines Project interest rate swaps of $744 million and a decrease in the gain on the Calcasieu Pass Project interest rate swaps of $14 million as a result of smaller increases in the interest rates during the nine months ended September 30, 2024, as compared to the same period in 2023.

Loss on Financing Transactions

Loss on financing transactions was $14 million for the nine months ended September 30, 2024, a $99 million, or 88%, decrease from $113 million during the nine months ended September 30, 2023. This decrease was primarily due to the write-off of debt issuance costs associated with the full prepayment of the Plaquemines Equity Bridge Facility during the nine months ended September 30, 2024, as compared to the write-off of debt issuance costs associated with the prepayment of our three year $500 million senior secured term loan facility due August 2025, or the VGLNG Corporate 2025 Term Loan, and the partial prepayments of the Plaquemines Equity Bridge Facility and our senior secured credit facilities for the Calcasieu Project, or the Calcasieu Pass Credit Facilities, during the nine months ended September 30, 2023.

 

122


Table of Contents

Income before Income Tax Expense

Income before income tax expense was $945 million for the nine months ended September 30, 2024, a $3.5 billion, or 79%, decrease from $4.5 billion during the nine months ended September 30, 2023. This decrease was primarily the result of the decrease in our income from operations and a decrease in our gain on derivatives, as discussed above.

Income Tax Expense

Income tax expense was $189 million for the nine months ended September 30, 2024, a $679 million, or 78%, decrease from $868 million during the nine months ended September 30, 2023 driven by a decrease in taxable income. Our effective tax rate was 20.0% for the nine months ended September 30, 2024, as compared to 19.4% during the same period in 2023. The 2024 effective tax rate was lower than the statutory income tax rate due to a combination of factors including guaranteed payments to non-controlling interests and non-deductible expenses.

Net Income

Net income was $756 million for the nine months ended September 30, 2024, a $2.9 billion, or 79%, decrease from $3.6 billion during the nine months ended September 30, 2023. This decrease was primarily the result of a decrease in income from operations due to lower revenue earned from the sale of LNG produced by the Calcasieu Project, partially offset by lower cost of sales, and a decrease in gain on derivatives, partially offset by a decrease in income tax expense, as discussed above.

Year Ended December 31, 2023 Compared to Year Ended December 31, 2022

The following table shows a summary of our results of operations for the periods indicated.

 

     Years ended December 31,     Change  
      2023       2022      ($)     (%)  
     ($ in millions)  

Revenue

   $ 7,897     $ 6,448     $ 1,449       22
  

 

 

   

 

 

   

 

 

   

 

 

 

Operating Expense

        

Cost of sales (exclusive of depreciation and amortization shown separately below)

     1,684       2,093       (409     (20 )% 

Operating and maintenance expense

     391       140       251       179

General and administrative expense

     224       191       33       17

Development expense

     490       311       179       58

Depreciation and amortization

     277       158       119       75

Insurance recoveries, net

     (19     —        (19     NM  
  

 

 

   

 

 

   

 

 

   

 

 

 

Total operating expense

     3,047       2,893       154       5
  

 

 

   

 

 

   

 

 

   

 

 

 

Income from Operations

     4,850       3,555       1,295       36

Other Income (Expense)

        

Interest income

     172       18       154       NM  

Interest expense, net

     (641     (592     (49     8

Gain on derivatives, net

     174       1,212       (1,038     (86 )% 

Gain (loss) on embedded derivative

     —        (14     14       NM  

Loss on financing transactions

     (123     (635     512       (81 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

Total other expense

     (418     (11     (407     NM  
  

 

 

   

 

 

   

 

 

   

 

 

 

Income before Income Tax Expense

     4,432       3,544       888       25
  

 

 

   

 

 

   

 

 

   

 

 

 

Income tax expense

     816       447       369       83
  

 

 

   

 

 

   

 

 

   

 

 

 

Net Income

   $ 3,616     $ 3,097     $ 519       17
  

 

 

   

 

 

   

 

 

   

 

 

 

 

NM Percentage not meaningful.

 

123


Table of Contents

Revenue

Revenue was $7.9 billion for the year ended December 31, 2023, a $1.4 billion, or 22%, increase from $6.4 billion during the year ended December 31, 2022. This increase was primarily due to $7.1 billion from higher LNG sales volumes, partially offset by a decrease of $5.8 billion due to lower net pricing. The Calcasieu Pass Project facilities were in service from an accounting perspective and generating revenue for the entire year ended December 31, 2023, as compared to being placed in service from an accounting perspective on a sequential basis between April and August 2022, and therefore generating revenue for only a portion of the year ended December 31, 2022. The proceeds attributable to test LNG sales generated prior to the Calcasieu Pass Project facilities being in service from an accounting perspective, and therefore recognized as construction in progress and not as revenue, were $1.8 billion for the year ended December 31, 2022.

Operating Expense

Operating expense was $3.0 billion for the year ended December 31, 2023, a $154 million, or 5%, increase from $2.9 billion during the year ended December 31, 2022. This increase was primarily a result of an increase in operating and maintenance expense. Other factors which had a lesser influence were increases in general and administrative expense, development expense, and depreciation and amortization expense. These were partially offset by a decrease in cost of sales and an increase in insurance recoveries, as explained below.

Cost of Sales

Cost of sales was $1.7 billion for the year ended December 31, 2023, a $409 million, or 20%, decrease from $2.1 billion during the year ended December 31, 2022. This decrease was due to $2.8 billion from lower natural gas prices and higher efficiency, partially offset by an increase of $2.4 billion from higher LNG sales volumes. The Calcasieu Pass Project facilities were in service from an accounting perspective and incurring cost of sales for the entire year ended December 31, 2023, as compared to being placed in service from an accounting perspective on a sequential basis between April and August 2022, and therefore incurring cost of sales for only a portion of the year ended December 31, 2022. The cost attributable to the production of test LNG sales incurred prior to the Calcasieu Pass Project facilities being in service from an accounting perspective, and therefore recognized as construction in progress and not as cost of sales, was $723 million for the year ended December 31, 2022.

Operating and Maintenance Expense

Operating and maintenance expense was $391 million for the year ended December 31, 2023, a $251 million, or 179%, increase from $140 million during the year ended December 31, 2022. This increase was primarily due to higher operating costs at the Calcasieu Pass Project to support ongoing commissioning and remediation work, personnel costs, and insurance, and higher operating costs in support of the Plaquemines Project primarily due to an increase in non-capitalizable personnel costs and ARO accretion.

General and Administrative Expense

General and administrative expense was $224 million for the year ended December 31, 2023, a $33 million, or 17%, increase from $191 million during the year ended December 31, 2022. This increase was primarily due to increased personnel costs due to an increase in employee headcount.

Development Expense

Development expense was $490 million for the year ended December 31, 2023, a $179 million, or 58%, increase from $311 million during the year ended December 31, 2022. This increase was primarily due to an increase in early development activities and personnel costs related to the CP2 LNG Project, partially offset by the Plaquemines Project being deemed probable in March 2022, and the majority of the costs to develop the facility subsequently being capitalized.

 

124


Table of Contents

Depreciation and Amortization Expense

Depreciation and amortization expense was $277 million for the year ended December 31, 2023, a $119 million, or 75%, increase from $158 million during the year ended December 31, 2022. This increase was primarily due to placing additional property, plant and equipment at the Calcasieu Pass Project in service from an accounting perspective throughout the year ended December 31, 2022.

Insurance Recoveries, Net

Insurance recoveries, net were $19 million for the year ended December 31, 2023, a $19 million increase from the year ended December 31, 2022. This increase was mainly due to the recognition of the Company’s portion of insurance claims received in connection with Hurricane Laura storm costs during the year ended December 31, 2023, with no similar activity during the year ended December 31, 2022.

Income from Operations

Income from operations was $4.9 billion for the year ended December 31, 2023, a $1.3 billion, or 36%, increase from $3.6 billion during the year ended December 31, 2022. This increase was primarily a result of higher sales volumes and margin earned from the sale of LNG produced by the Calcasieu Pass Project assets placed in service from an accounting perspective between April and August 2022.

Other Expense

Other expense was $418 million for the year ended December 31, 2023, a $407 million increase from $11 million during the year ended December 31, 2022. This increase was primarily the result of a decrease in the gain on derivatives, net, as compared to the same period in 2022. Another factor which had a lesser influence was an increase in our interest expense, net as compared to the same period in 2022. These increases in other expense were partially offset by a decrease in our loss on financing transactions, a loss on embedded derivative that did not recur in 2023, and an increase in interest income, as explained below.

Interest Income

Interest income was $172 million for the year ended December 31, 2023, a $154 million increase from $18 million during the year ended December 31, 2022. This increase was primarily due to larger average cash balances and higher interest rates during the year ended December 31, 2023 compared to the year ended December 31, 2022.

Interest Expense, Net

Interest expense, net was $641 million for the year ended December 31, 2023, a $49 million, or 8%, increase from $592 million during the year ended December 31, 2022. This increase was primarily due to higher interest costs associated with increased debt outstanding and higher interest rates. These increases were partially offset by higher capitalized interest, primarily at the Plaquemines Project and Corporate, as a result of more interest meeting the threshold for capitalization, partially offset by a reduction in capitalized interest at the Calcasieu Pass Project due to the assets being placed in service from an accounting perspective in 2022.

Gain on Derivatives, Net

Gain on derivatives, net was $174 million for the year ended December 31, 2023, a $1.0 billion, or 86%, decrease from $1.2 billion during the year ended December 31, 2022. This decrease was primarily due to a reduction in the gain on the Plaquemines Project interest rate swaps of $838 million, due to smaller changes in the forward interest rate curves over higher notional, and a reduction in the gain on the Calcasieu Pass Project interest rate swaps of $197 million, due to smaller changes in the forward interest rate curves over lower notional during the year ended December 31, 2023 compared to the year ended December 31, 2022.

 

125


Table of Contents

Loss on Embedded Derivative

Loss on embedded derivative was nil for the year ended December 31, 2023, a $14 million decrease from the loss of $14 million during the year ended December 31, 2022. This decrease was due to the full prepayment of the 2024 Convertible Note in December 2022, with no corresponding change in the fair value of embedded derivatives during the same period in 2023.

Loss on Financing Transactions

Loss on financing transactions was $123 million for the year ended December 31, 2023, a $512 million, or 81%, decrease from $635 million during the year ended December 31, 2022. This decrease was primarily due to the write-off of debt issuance costs associated with the prepayment of the VGLNG Corporate 2025 Term Loan and the partial prepayments of the Calcasieu Pass Credit Facilities and the Plaquemines Equity Bridge Facility during the year ended December 31, 2023, compared to the write-off of debt issuance costs associated with the prepayment of the convertible notes due 2024, or the 2024 Convertible Notes, the refinancing of the VGLNG Corporate 2025 Term Loan, and the reduction and repayment of debt associated with the Plaquemines Project during the year ended December 31, 2022.

Income before Income Tax Expense

Income before income tax expense was $4.4 billion for the year ended December 31, 2023, a $888 million, or 25%, increase from $3.5 billion during the year ended December 31, 2022. The increase was primarily a result of the increase in our income from operations.

Income Tax Expense

Income tax expense was $816 million for the year ended December 31, 2023, a $369 million, or 83%, increase from $447 million during the year ended December 31, 2022. Our effective tax rate was 18.4% for the year ended December 31, 2023 compared to 12.5% for the year ended December 31, 2022. The 2023 effective tax rate was impacted by income tax benefits related to the foreign derived intangible income, or FDII, deduction and other permanent GAAP to tax differences. The 2022 effective tax rate was impacted by an income tax benefit from the release of a significant portion of our valuation allowance. This tax benefit was partially offset by tax expense related to the disallowed interest expense and disallowed losses from the prepayment of the 2024 Convertible Note.

Net Income

Net income was $3.6 billion for the year ended December 31, 2023, a $519 million, or 17%, increase from $3.1 billion during the year ended December 31, 2022. This increase was primarily a result of an increase in income from operations due to higher revenue, partially offset by cost of sales, from the sale of LNG produced by the Calcasieu Pass Project partially offset by an increase in income tax expense and a decrease in gain on derivatives, net, as explained above.

 

126


Table of Contents

Year Ended December 31, 2022 Compared to Year Ended December 31, 2021

The following table shows a summary of our results of operations for the periods indicated.

 

    Years ended December 31,     Change  
     2022       2021      ($)     (%)  
    ($ in millions)  

Revenue

  $ 6,448     $ —      $ 6,448       NM  

Operating Expense

       

Cost of sales (exclusive of depreciation and amortization shown separately below)

    2,093       —        2,093       NM  

Operating and maintenance expense

    140       58       82       141

General and administrative expense

    191       89       102       115

Development expense

    311       188       123       65

Depreciation and amortization

    158       6       152       NM  

Insurance recoveries, net

    —        (4     4       (100 )% 
 

 

 

   

 

 

   

 

 

   

 

 

 

Total operating expense

    2,893       337       2,556       NM  
 

 

 

   

 

 

   

 

 

   

 

 

 

Income (Loss) from Operations

    3,555       (337     3,892       NM  

Other Income (Expense)

       

Interest income

    18       —        18       NM  

Interest expense, net

    (592     (52     (540     NM  

Gain on derivatives, net

    1,212       38       1,174       NM  

Gain (loss) on embedded derivative

    (14     12       (26     NM  

Loss on financing transactions

    (635     (97     (538     NM  
 

 

 

   

 

 

   

 

 

   

 

 

 

Total other expense

    (11     (99     88       (89 )% 
 

 

 

   

 

 

   

 

 

   

 

 

 

Income (Loss) before Income Tax Expense

    3,544       (436     3,980       NM  

Income tax expense

    447       —        447       NM  
 

 

 

   

 

 

   

 

 

   

 

 

 

Net Income (Loss)

  $ 3,097     $ (436   $ 3,533       NM  
 

 

 

   

 

 

   

 

 

   

 

 

 

 

NM Percentage not meaningful.

Revenue

Revenue was $6.4 billion for the year ended December 31, 2022, a $6.4 billion increase from the year ended December 31, 2021, during which there was no revenue. This increase was due to the sale of the commissioning cargos produced by the Calcasieu Pass Project assets that were placed in service from an accounting perspective between April and August 2022. We recognized no revenue in the prior period because there were no sales of commissioning cargos.

Operating Expense

Operating expense was $2.9 billion for the year ended December 31, 2022, a $2.6 billion increase from $337 million for the year ended December 31, 2021. The increase was primarily a result of an increase in cost of sales, compared to no cost of sales incurred for the year ended December 31, 2021. Other factors which had a lesser influence were increases in depreciation and amortization expense, development expense, operating and maintenance expense, general and administrative expense, and a decrease in insurance recoveries, net of loss from hurricane, as explained below.

Cost of Sales

Cost of sales was $2.1 billion for the year ended December 31, 2022, a $2.1 billion increase from the year ended December 31, 2021, during which we incurred no cost of sales. This increase was largely for the purchase

 

127


Table of Contents

of natural gas due to the sale of commissioning cargos produced by the Calcasieu Pass Project assets that were placed in service from an accounting perspective between April and August 2022. We incurred no cost of sales in the prior period because there were no sales of commissioning cargos.

Operating and Maintenance Expense

Operating and maintenance expense was $140 million for the year ended December 31, 2022, a $82 million, or 141%, increase from $58 million for the year ended December 31, 2021. This increase was due primarily to higher operating costs, including external services, personnel costs, insurance, materials and IT costs in support of LNG production at the Calcasieu Pass Project, during the year ended December 31, 2022, compared to lower pre-production operational support during 2021, a portion of which was capitalized.

General and Administrative Expense

General and administrative expense was $191 million for the year ended December 31, 2022, a $102 million, or 115%, increase from $89 million for the year ended December 31, 2021. The increase was primarily due to increased compensation costs and, to a lesser extent, employee headcount, and higher consulting fees.

Development Expense

Development expense was $311 million for the year ended December 31, 2022, a $123 million, or 65%, increase from $188 million for the year ended December 31, 2021. This increase was primarily due to an increase in early construction-related activity at the Plaquemines Project prior to the project being deemed probable, higher engineering and environmental costs at the CP2 LNG Project, and a fee to secure future construction capacity incurred in 2022.

Depreciation and Amortization

Depreciation and amortization expense was $158 million for the year ended December 31, 2022, a $152 million increase from $6 million for the year ended December 31, 2021. This increase was mainly attributable to placing $6.8 billion of property, plant and equipment at the Calcasieu Pass Project in service from an accounting perspective during 2022.

Insurance Recoveries, Net

Insurance recoveries, net were nil for the year ended December 31, 2022, a $4 million, or 100%, decrease from a recovery of $4 million for the year ended December 31, 2021. This decrease was mainly due to our portion of insurance recoveries for Hurricane Laura received in 2021.

Income (Loss) from Operations

Income from operations was $3.6 billion for the year ended December 31, 2022, a $3.9 billion increase from our loss from operations of $337 million for the year ended December 31, 2021. This increase was primarily a result of the increase in revenue, partially offset by cost of sales, from to the sale of LNG produced by the Calcasieu Pass Project assets placed in service from an accounting perspective between April and August 2022.

Other Expense

Other expense was $11 million for the year ended December 31, 2022, a $88 million, or 89%, decrease from $99 million for the year ended December 31, 2021. This decrease was primarily a result of an increase in the gain on derivatives, compared to the same period in 2021. Another factor which had a lesser influence was an increase

 

128


Table of Contents

in interest income, compared to the same period in 2021. These increases were partially offset by an increase in loss on financing transactions, an increase in interest expense, net, and an unfavorable change in the gain (loss) on embedded derivative, as explained below.

Interest Income

Interest income was $18 million for the year ended December 31, 2022, a $18 million increase from nil for the year ended December 31, 2021. This increase was primarily due to higher average cash balances during the year ended December 31, 2022, compared to the year ended December 31, 2021.

Interest Expense, Net

Interest expense, net was $592 million for the year ended December 31, 2022, a $540 million increase from $52 million for the year ended December 31, 2021. This increase was primarily due to an increase in non-capitalizable interest of $210 million in Corporate, other and eliminations., $165 million at the Calcasieu Pass Project, and $92 million at the Plaquemines Project as a result of higher debt balances and less interest that met the threshold for capitalization, as well as an increase in commitment fees of $72 million primarily associated with undrawn commitments supporting the Plaquemines Project.

Gain on Derivatives, Net

Gain on derivatives, net was $1.2 billion for the year ended December 31, 2022, a $1.2 billion increase from $38 million for the year ended December 31, 2021. This increase was primarily due to an increase in the gain on interest rate swaps held by the Plaquemines Project of $1.1 billion, which were executed in the fourth quarter of 2021 and the first half of 2022, due to favorable changes in the forward SOFR curve and the expiration of the FID contingency and an increase in the gain on interest rate swaps held by the Calcasieu Pass Project of $99 million, due to favorable changes in the forward LIBOR curve during the year ended December 31, 2022, compared to the same period in 2021.

Gain (Loss) on Embedded Derivative

Loss on embedded derivative was $14 million for the year ended December 31, 2022, a $26 million decrease from a gain on embedded derivative of $12 million for the year ended December 31, 2021. This decrease was mainly due to an increase in the fair value of the embedded derivative liability during the year ended December 31, 2022, compared to a decrease in the fair value of the embedded derivative liability in the same period in 2021.

Loss on Financing Transactions

Loss on financing transactions was $635 million for the year ended December 31, 2022, a $538 million increase from $97 million for the year ended December 31, 2021. This increase was primarily due to a loss of $411 million resulting from the prepayment of the 2024 Convertible Notes, a loss of $159 million due to the write off of deferred issuance costs associated with the repayment of the two-year secured credit facility entered into by Plaquemines LNG Holdings, LLC, or PL Holdings, in May 2022 for Phase 1 of the Plaquemines Project, or the PL Holdings Credit Facility, the extinguishment of the two-year secured backstop credit facility entered into by Plaquemines LNG Funding, LLC in May 2022, or the PL Funding Backstop Facility, and the repayment of the bridge loan facility entered into in November 2021 by PL Holdings, or the Plaquemines Bridge Loan Facility, and a loss of $64 million due to the refinancing of the senior secured term loan facility entered into by VGLNG due 2024, or the VGLNG Corporate 2024 Term Loan, and the VGLNG Corporate 2025 Term Loan, compared to a loss of $97 million during the year ended December 31, 2021 primarily due to the write-off of deferred issuance costs associated with the partial termination of the Calcasieu Pass Credit Facilities.

 

129


Table of Contents

Income (Loss) before Income Tax Expense

Income before income tax expense was $3.5 billion for the year ended December 31, 2022, a $4.0 billion increase from a loss before income tax expense of $436 million for the year ended December 31, 2021. The increase in our income (loss) before income tax expense was primarily a result of the increase in our income from operations.

Income Tax Expense

Income tax expense was $447 million for the year ended December 31, 2022, a $447 million increase from nil for the year ended December 31, 2021. This increase was primarily due to the recognition of income tax expense from operations of $714 million and permanent tax differences associated with the 2024 Convertible Notes of $151 million, partially offset by a $416 million income tax benefit related to the release of a significant portion of the valuation allowance on U.S. federal deferred tax assets during the year ended December 31, 2022.

Net Income (Loss)

Net income was $3.1 billion for the year ended December 31, 2022, a $3.5 billion increase from our net loss of $436 million for the year ended December 31, 2021. The increase was primarily a result of an increase in our income (loss) before income tax expense, which was partially offset by an increase in income tax expense of $447 million as discussed above.

Segment Results of Operations

We have three reportable segments, which consist of the Calcasieu Pass Project, the Plaquemines Project, and the CP2 LNG Project. Each reportable segment includes activity of both the respective liquefaction and export terminal and the associated pipeline that will supply the natural gas to that facility. Activities relating to certain development stage projects and our shipping business, overhead costs not directly associated with our LNG projects (for example, general and administrative and marketing expenses) and inter-segment eliminations are not material and therefore are included in Corporate, other and eliminations.

Three Months Ended September 30, 2024 Compared to Three Months Ended September 30, 2023

The following table shows a summary of our segment income (loss) from operations for the periods indicated:

 

     Three months ended
September 30,
    Change  
      2024       2023      ($)     (%)  
     ($in millions)  

Income (loss) from operations:

        

Calcasieu Pass Project

   $ 540     $ 534     $ 6       1

Plaquemines Project

     (57     (59     2       (3 )% 

CP2 LNG Project

     (106     (120     14       (12 )% 

Corporate, other and eliminations(1)

     (188     (46     (142     NM  
  

 

 

   

 

 

   

 

 

   

 

 

 

Total

   $ 189     $ 309     $ (120     (39 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

 

(1)

Includes costs associated with the CP3 Project, the Delta Project, certain other development stage projects, our shipping business and certain corporate activities.

NM Percentage not meaningful.

 

130


Table of Contents

Calcasieu Pass Project

During the three months ended September 30, 2024, the Calcasieu Pass Project had income from operations of $540 million, a $6 million, or 1%, increase from $534 million during the three months ended September 30, 2023.

This increase was primarily due to:

 

   

a net decrease in cost of sales of $54 million driven by the combined impact of a decrease in the net cost of natural gas and improved plant efficiency of $39 million and a decrease in LNG sales volumes of $15 million,

partially offset by:

 

   

lower revenue of $29 million due to lower LNG sales volumes of commissioning cargos of $47 million, partially offset by higher net LNG sales prices of $17 million,

 

   

an increase in depreciation and amortization of $12 million due to adjustments to the cost basis of certain assets in 2024, and

 

   

an increase in operating and maintenance expense of $7 million primarily due to higher legal costs.

The Calcasieu Pass Project sold a portion of its LNG to VG Commodities for the ultimate sale by VG Commodities to its customers on a delivered basis. As of September 30, 2024, this LNG was in transit. Therefore, $72 million of net revenue and cost of sales from the Calcasieu Pass Project included in the results above is eliminated in consolidation. See “—Corporate, Other and Eliminations” below for more detail.

Plaquemines Project

During the three months ended September 30, 2024, the Plaquemines Project had a loss from operations of $57 million, a $2 million, or 3%, decrease from $59 million during the three months ended September 30, 2023. This decrease was primarily due to a decrease in operating and maintenance expense of $7 million mainly resulting from a decrease in non-capitalizable personnel costs, partially offset by an increase in ARO accretion expense.

CP2 LNG Project

During the three months ended September 30, 2024, the CP2 LNG Project had a loss from operations of $106 million, a $14 million, or 12%, decrease from $120 million during the three months ended September 30, 2023. This decrease was primarily due to a decrease in development expense of $19 million mainly resulting from lower costs for engineering and environmental services, partially offset by higher lease costs.

Corporate, Other and Eliminations

During the three months ended September 30, 2024, Corporate, other and eliminations had a loss from operations of $188 million, a $142 million increase from $46 million during the three months ended September 30, 2023. This increase was primarily due to an increase in development expense of $34 million for development stage projects, an increase in operating and maintenance expense of $17 million due to higher costs related to the operation and management of our LNG tankers, an increase in general and administrative expense of $15 million resulting from higher personnel costs caused by an increase in employee headcount, and increased sponsorship activities. In addition, Corporate, other and eliminations recognized an inter-segment elimination of $72 million related to the sale of LNG from the Calcasieu Pass Project to VG Commodities, which was in transit at September 30, 2024, because it was sold by VG Commodities to its customers on a delivered basis and will be recognized upon ultimate delivery to those customers in the fourth quarter of 2024.

 

131


Table of Contents

Nine Months Ended September 30, 2024 Compared to Nine Months Ended September 30, 2023

The following table shows a summary of our segment income (loss) from operations for the periods indicated:

 

     Nine months ended
September 30,
    Change  
      2024       2023      ($)     (%)  
     ($in millions)  

Income (loss) from operations:

        

Calcasieu Pass Project

   $ 2,066     $ 4,625     $ (2,559     (55 )% 

Plaquemines Project

     (163     (132     (31     23

CP2 LNG Project

     (396     (233     (163     70

Corporate, other and eliminations(1)

     (338     (147     (191     130
  

 

 

   

 

 

   

 

 

   

 

 

 

Total

   $ 1,169     $ 4,113     $ (2,944     (72 )% 
  

 

 

   

 

 

   

 

 

   

 

 

 

 

(1)

Includes costs associated with the CP3 Project, the Delta Project, certain other development stage projects, our shipping business and certain corporate activities.

Calcasieu Pass Project

During the nine months ended September 30, 2024, the Calcasieu Pass Project had income from operations of $2.1 billion, a $2.6 billion, or 55%, decrease from $4.6 billion during the nine months ended September 30, 2023.

This decrease was primarily due to:

 

   

a decrease in revenue of $2.7 billion due to a decrease in LNG sales prices of $3.2 billion, partially offset by higher LNG sales volumes of commissioning cargos of $506 million; and

 

   

an increase in operating and maintenance expense of $63 million primarily due to higher operating costs to support ongoing commissioning and remediation work and legal costs.

These decreases to income from operations were partially offset by:

 

   

a net decrease in cost of sales of $231 million due to the combined impact of a decrease in the net cost of natural gas and improved plant efficiency of $298 million, partially offset by an increase in LNG sales volumes of $67 million; and

 

   

a decrease in development expense of $22 million primarily due to lower legal costs related to contractor disputes.

The Calcasieu Pass Project sold a portion of its LNG sales to VG Commodities. As of September 30, 2024, this LNG was in transit to be sold at its end destination. Therefore, $72 million of net revenue and cost of sales from the Calcasieu Pass Project included in the results above is eliminated in consolidation. See “—Corporate, Other and Eliminations” below for more detail.

Plaquemines Project

During the nine months ended September 30, 2024, the Plaquemines Project had a loss from operations of $163 million, a $31 million, or 23%, increase from $132 million during the nine months ended September 30, 2023. This increase was primarily due to an increase in operating and maintenance expense of $18 million primarily due to an increase in ARO accretion and non-capitalizable personnel costs, and an increase in general and administrative expenses of $6 million due to higher costs for administrative services.

 

132


Table of Contents

CP2 LNG Project

During the nine months ended September 30, 2024, the CP2 LNG Project had a loss from operations of $396 million, a $163 million, or 70%, increase from $233 million during the nine months ended September 30, 2023. This increase was primarily driven by an increase in development expense of $150 million primarily due to higher costs for engineering and environmental services and lease costs.

Corporate, Other and Eliminations

During the nine months ended September 30, 2024, Corporate, other and eliminations had a loss from operations of $338 million, a $191 million, or 130%, increase from $147 million during the nine months ended September 30, 2023. This increase was primarily driven by an increase in development expense of $53 million for development stage projects, an increase in general and administrative expenses of $41 million primarily due to higher personnel costs associated with an increase in employee headcount, increased sponsorship activities, our entry into the Venture Global Management Services Agreement (as defined in “Certain Relationships and Related Party Transactions—Management Services Agreements—Venture Global Management Services Agreement”) with VG Partners at the end of the third quarter of 2023, and an increase in operating and maintenance expense of $19 million related to the operation and management of our LNG tankers. In addition, Corporate, other and eliminations recognized an inter-segment elimination of $72 million related to the sale of LNG from the Calcasieu Pass Project to VG Commodities, which was in transit at September 30, 2024, because it was sold by VG Commodities to its customers on a delivered basis and will be recognized upon ultimate delivery to those customers in the fourth quarter of 2024.

Year Ended December 31, 2023 Compared to Year Ended December 31, 2022

The following table shows a summary of our segment income (loss) from operations for the periods indicated:

 

     Years ended December 31,      Change  
      2023        2022       ($)      (%)  
     ($ in millions)  

Income (loss) from operations:

           

Calcasieu Pass Project

   $ 5,598      $ 4,042      $ 1,556        38

Plaquemines Project

     (187      (269      82        (30 )% 

CP2 LNG Project

     (362      (34      (328      NM  

Corporate, other and eliminations.(1)

     (199      (184      (15      8
  

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ 4,850      $ 3,555      $ 1,295        36
  

 

 

    

 

 

    

 

 

    

 

 

 

 

(1)

Includes costs associated with the CP3 Project, the Delta Project, certain other development stage projects, our shipping business and certain corporate activities.

NM Percentage not meaningful.

Calcasieu Pass Project

For the year ended December 31, 2023, the Calcasieu Pass Project had income from operations of $5.6 billion, a $1.6 billion, or 38%, increase from $4.0 billion during the year ended December 31, 2022. This increase was primarily due to:

 

   

an increase in revenue of $1.4 billion primarily due to $7.1 billion from higher LNG sales volumes, partially offset by a decrease of $5.8 billion due to lower net pricing. The Calcasieu Pass Project facilities were in service from an accounting perspective and generating revenue for the entire year ended December 31, 2023, as compared to being placed in service from an accounting perspective on a sequential basis between April and August 2022, and therefore generating revenue for only a portion of the year ended December 31, 2022. The proceeds attributable to test LNG sales generated prior to the

 

133


Table of Contents
 

Calcasieu Pass Project facilities being in service from an accounting perspective, and therefore recognized as construction in progress and not revenue, were $1.8 billion for the year ended December 31, 2022; and

 

   

a decrease in cost of sales of $409 million due to $2.8 billion from lower natural gas prices and higher efficiency, partially offset by an increase of $2.4 billion from higher LNG sales volumes. The Calcasieu Pass Project facilities were in service from an accounting perspective and incurring cost of sales for the entire year ended December 31, 2023, as compared to being placed in service from an accounting perspective on a sequential basis between April and August 2022, and therefore incurring cost of sales for only a portion of the year ended December 31, 2022. The cost attributable to the production of test LNG sales incurred prior to the Calcasieu Pass Project facilities being in service from an accounting perspective, and therefore recognized as construction in progress and not cost of sales, was $723 million for the year ended December 31, 2022.

These net favorable changes were partially offset by:

 

   

an increase in operating and maintenance expense of $188 million, primarily due to higher operating costs in support of LNG production including costs to support ongoing commissioning and remediation work, personnel costs and insurance costs; and

 

   

an increase in depreciation and amortization expense of $112 million, primarily due to placing additional property, plant and equipment at the Calcasieu Pass Project in service from an accounting perspective throughout the year ended December 31, 2022.

Plaquemines Project

For the year ended December 31, 2023, the Plaquemines Project had a loss from operations of $187 million, a $82 million, or 30%, decrease from $269 million during the year ended December 31, 2022. This decrease was primarily due to a decrease in development expense of $184 million due to the Plaquemines Project being deemed probable in March 2022, and the costs to develop and construct the facility largely being capitalized in 2023. This decrease was partially offset by an increase in operating and maintenance expense of $64 million due to higher operating costs primarily due to an increase in non-capitalizable personnel costs and ARO accretion and an increase in general and administrative expenses of $37 million due to higher costs for administrative services.

CP2 LNG Project

For the year ended December 31, 2023, the CP2 LNG Project had a loss from operations of $362 million, a $328 million increase from $34 million during the year ended December 31, 2022. This increase was primarily driven by an increase in development expense of $328 million primarily due to early development, pre-construction and personnel costs related to the CP2 LNG Project that were not capitalizable.

Corporate, Other and Eliminations

For the year ended December 31, 2023, Corporate, other and eliminations. had a loss from operations of $199 million, a $15 million, or 8%, increase from $184 million during the year ended December 31, 2022. This increase was primarily driven by an increase in development expense of $14 million, primarily due to an increase in costs related to a Corporate development project, partially offset by a lower fee to secure future construction capacity during the year ended December 31, 2023.

 

134


Table of Contents

Year Ended December 31, 2022 Compared to Year Ended December 31, 2021

The following table shows a summary of our segment income (loss) from operations for the periods indicated:

 

     Years ended December 31,      Change  
      2022        2021       ($)      (%)  
     ($ in millions)  

Income (loss) from operations:

           

Calcasieu Pass Project

   $ 4,042      $ (85    $ 4,127        NM  

Plaquemines Project

     (269      (158      (111      70

CP2 LNG Project

     (34      (15      (19      127

Corporate, other and eliminations.(1)

     (184      (79      (105      133
  

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ 3,555      $ (337    $ 3,892        NM  
  

 

 

    

 

 

    

 

 

    

 

 

 

 

(1)

Includes costs associated with the CP3 Project, the Delta Project, certain other development stage projects, our shipping business and certain corporate activities.

NM Percentage not meaningful.

Calcasieu Pass Project

For the year ended December 31, 2022, the Calcasieu Pass Project had income from operations of $4.0 billion, which represented a $4.1 billion favorable change from a loss from operations of $85 million for the year ended December 31, 2021. This increase was primarily driven by an increase in revenue of $6.4 billion due to the sale of LNG produced by the Calcasieu Pass Project assets that were placed in service from an accounting perspective between April and August 2022, compared to no revenue generated for the corresponding period in 2021. This increase was partially offset by an increase in the cost of sales (largely from the purchase of natural gas) of $2.1 billion, due to the sale of LNG produced by Calcasieu Pass Project assets that were placed in service from an accounting perspective, compared to no cost of sales for the corresponding period in 2021. Other factors which had a lesser influence were an increase in depreciation and amortization expense of $142 million, which was mainly attributable to placing $6.8 billion of property, plant and equipment in service from an accounting perspective during 2022 and an increase in operating and maintenance expense of $73 million, primarily due to higher operating costs, including insurance, external services, personnel costs, materials, and IT costs in support of LNG production during the year ended December 31, 2022, compared to lower pre-production operational support, a portion of which was capitalized during year ended December 31, 2021.

Plaquemines Project

For the year ended December 31, 2022, the Plaquemines Project had a loss from operations of $269 million which represented a $111 million, or 70%, increase from $158 million for the year ended December 31, 2021. This increase was primarily the result of higher development expense of $76 million due to increased development and construction-related activities during the period when the project was not yet deemed probable as well as an increase in general and administrative expenses of $19 million as a result of higher costs for administrative services.

CP2 LNG Project

For the year ended December 31, 2022, the CP2 LNG Project had a loss from operations of $34 million, which represented a $19 million, or 127%, increase from $15 million for the year ended December 31, 2021. This increase was the result of higher development expense of $20 million, primarily due to engineering and environmental costs related to the CP2 LNG Project during the year ended December 31, 2022.

Corporate, Other and Eliminations

For the year ended December 31, 2022, Corporate, other and eliminations. had a loss from operations of $184 million, which represented a $105 million, or 133%, increase from $79 million for the year ended

 

135


Table of Contents

December 31, 2021. This increase was the result of higher development expense of $19 million, primarily due to a fee to secure future manufacturing capacity as well as an increase in general and administrative expense of $84 million, mainly resulting from increased compensation costs and, to a lesser extent, employee headcount, and higher consulting fees during the year ended December 31, 2022.

Liquidity and Capital Resources

General

We have a limited operational history and we did not generate any LNG sales proceeds prior to 2022. We may incur losses as we continue to construct and develop our projects and explore the development of other potential natural gas liquefaction and export projects.

Funding Requirements

The operation, commissioning, construction and development of our projects requires significant capital expenditures.

We currently estimate that the total project costs for the Calcasieu Project will be approximately $9.8 billion, including EPC contractor profit and contingency, owners’ costs and financing costs, and we expect that the remaining project costs to achieve COD for the Calcasieu Project will be funded with cash held in cash reserve accounts pursuant to our project financing arrangements and reflected as restricted cash in our financial statements at the Calcasieu Project in an amount expected to be necessary to complete the project and achieve COD under the Calcasieu Foundation SPAs. For the Calcasieu Project, we obtained approximately $6.6 billion of project-level debt financing and $1.3 billion of equity financing for its construction and development.

We currently estimate that the total project costs for the Plaquemines Project will be approximately $22 billion to $23 billion, including EPC contractor profit and contingency, owners’ costs and financing costs. Of the total project costs for the Plaquemines Project, approximately $17.7 billion had been paid for as of September 30, 2024. For the Plaquemines Project, we have obtained approximately $15.0 billion of project-level debt financing comprised of an approximately $12.9 billion term loan facility and $2.1 billion working capital revolving facility, and have made an aggregate of approximately $8.1 billion of equity contributions. As of September 30, 2024, approximately $11.5 billion of such project-level debt financing was outstanding, and we had additional available borrowing capacity of approximately $3.5 billion thereunder. We believe we have sufficient project-level cash, borrowing capacity under our existing project-level debt financing, and access to substantial commissioning cargo proceeds to fund the completion of the Plaquemines Project based on our current estimate of the total project costs. However, it is possible that we may make additional equity contributions to the extent that total project costs exceed the low-end of the range of estimated total project costs above and that such costs exceed the available project-level debt and equity financing and net proceeds from the sale of commissioning cargos.

We currently estimate that the total project costs for the CP2 Project will be approximately $27 billion to $28 billion, including EPC contractor profit and contingency, owners’ costs and financing costs. Of the total project costs for the CP2 Project, approximately $3.1 billion had been paid for as of September 30, 2024. Given that we have not executed certain contracts to construct the CP2 Project, including the EPC contract with respect to Phase 2 of the CP2 Project, this estimate is based upon the contracts that we have in place for the CP2 Project and our construction cost experiences with the Calcasieu Project and the Plaquemines Project. The cost estimate for the CP2 Project reflects the current inflationary environment, and may be higher, potentially materially, compared to our current estimates as a result of many factors. In addition, we expect to construct longer pipelines for the CP2 Project than for the Calcasieu Project and the Plaquemines Project. Furthermore, our cost estimates might change due to factors such as unexpected delays in the construction or commissioning of our projects, the execution of any repair or warranty work and change orders or amendments to certain material construction contracts, including final terms of or amendments to any EPC contract for such projects, and/or other

 

136


Table of Contents

construction or supply contracts. For more details on these risks, see “Risk Factors—Risks Relating to Our Projects and Other Assets—Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.”

We currently estimate that the total project costs for the CP3 Project and the Delta Project will be approximately $44 billion to $45 billion and $37 billion to $38 billion, respectively, in each case including EPC contractor profit and contingency, owners’ costs and financing costs. Given that we have not executed EPC contracts with respect to any portion of the CP3 Project or any portion of the Delta Project, and that no substantial construction work has been undertaken on either of those projects to date, these estimates are based upon our construction cost experiences with the Calcasieu Project, the Plaquemines Project, and the contracts that we have executed for the CP2 Project. The cost estimates for the CP3 Project and the Delta Project reflect the current inflationary environment, and may be higher, potentially materially, compared to our current estimates as a result of many factors. In addition, we expect to construct longer pipelines for the CP3 Project and the Delta Project than for the Calcasieu Project and the Plaquemines Project. Furthermore, our cost estimates might change due to factors such as unexpected delays in the construction or commissioning of our projects, the execution of any repair or warranty work and change orders or amendments to certain material construction contracts, including final terms of or amendments to any EPC contract for such projects, and/or other construction or supply contracts. For more details on these risks, see “Risk Factors—Risks Relating to Our Projects and Other Assets—Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.” As of September 30, 2024, no financing (equity nor debt) has been obtained for the CP2 Project, the CP3 Project, or the Delta Project.

We intend to finance the construction and development of the CP2 Project, the CP3 Project, the Delta Project, and any bolt-on expansions or future LNG projects as well as the related owners’ costs through one or more sources of debt and equity financing. The amount of project-level equity funding that is required for any of our projects relative to the amount of project-level debt financing may differ between our projects. Generally, we expect to finance approximately 50% to 75% of the anticipated construction costs of each of our projects with project-level debt financing (which may include limited recourse debt), and the remaining 25% to 50% with project-level equity (which may consist of equity contributions by us, equity financing transactions, mezzanine financing and/or other similar financing alternatives). The final terms and availability of such debt and equity financing will depend on various factors, including market conditions at the time. We may consider alternative structures to raise capital for those projects and, as a result, there can be no assurance that the financing structure for the CP2 Project, the Delta Project, the CP3 Project or any future project we may develop will be similar to those used for the Calcasieu Project and the Plaquemines Project.

 

137


Table of Contents

Contractual Obligations

We have contractual obligations involving commitments to third parties that impact our liquidity and capital resource needs. In addition to the construction and development obligations and commitments for the liquefaction and pipeline projects discussed above, the following table summarizes our contractual obligations as of September 30, 2024:

 

     Years ended December 31,  
     2024-2025      2026-2029      Thereafter      Total  
     ($ in millions)  

Operating contracts

           

Natural gas supply and transportation(1)

   $ 3,222      $ 7,341      $ 6,099      $ 16,662  

Leases

     146        338        1,125        1,609  

Regasification capacity

     7        123        754        884  

Other

     28        36        16        80  

Other capital projects

           

Pipeline development projects

     225        878        —         1,103  

LNG tankers

     952        288        —         1,240  
  

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ 4,580      $ 9,004      $ 7,994      $ 21,578  
  

 

 

    

 

 

    

 

 

    

 

 

 

 

(1)

Includes contractual obligations under (i) natural gas forward purchase contracts for the supply of feed gas to the Calcasieu Project and the Plaquemines Project for which we intend to take physical delivery through March 2030, and (ii) long-term natural gas firm transportation service agreements with various interstate pipeline companies to secure natural gas transportation requirements for the Calcasieu Project and the Plaquemines Project through June 2045.

In addition, we have significant debt and associated interest expense obligations at our subsidiaries, consisting of debt incurred by VGLNG as well as debt incurred by subsidiaries of VGLNG in connection with financing the Calcasieu Project and the Plaquemines Project. We anticipate obtaining significant additional financing and incurring related financing fees and interest expense in connection with the CP2 Project, the CP3 Project, the Delta Project, our pipeline development projects, our LNG tankers, and any bolt-on expansions or future LNG projects.

Outstanding debt and associated interest expense obligations of subsidiaries of VGLNG have no recourse to nor are guaranteed by the Company or VGLNG (other than $84 million of indebtedness outstanding at September 30, 2024 that was incurred by a subsidiary and is guaranteed by VGLNG in certain circumstances). The following table summarizes our debt and associated interest expense obligations of subsidiaries of VGLNG as of September 30, 2024:

 

     Years ended December 31,  
     2024-2025      2026-2029      Thereafter      Total  
     ($ in millions)  

Principal maturities(1)(2)

   $ 236      $ 12,494      $ 3,500      $ 16,230  

Interest payments(3)

     1,006        1,489        328        2,823  
  

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ 1,242      $ 13,983      $ 3,828      $ 19,053  
  

 

 

    

 

 

    

 

 

    

 

 

 

 

(1)

Reflects aggregate contractual maturities for outstanding principal as of September 30, 2024. See “Description of Material Financing” and “Note 11—Debt” to our annual financial statements, included elsewhere in this prospectus, for more information.

(2)

Excludes $1.5 billion of redeemable preferred shares of Calcasieu Pass Funding, presented as Redeemable stock of subsidiary which is redeemable at the option of the holder thereof upon the occurrence of certain events. See “Description of Material Financing—Project Equity Financing—Calcasieu Pass Funding, LLC Preferred Units.”

(3)

Inclusive of the expected settlements of interest rate swaps that economically hedge the variable rate interest incurred by the Calcasieu Project and the Plaquemines Project. See “Note 9—Debt” to our interim condensed consolidated financials, included elsewhere in this prospectus, for more information.

 

138


Table of Contents

Outstanding debt and associated interest expense obligations of VGLNG are secured by its equity interests in the direct wholly-owned subsidiaries of VGLNG that directly or indirectly own our LNG projects. The following table summarizes our debt and associated interest expense obligations of VGLNG as of September 30, 2024:

 

     Years ended December 31,  
     2024-2025      2026-2029      Thereafter      Total  
     ($ in millions)  

Principal maturities(1)(2)

   $ —       $ 5,250      $ 5,750      $ 11,000  

Interest payments(3)

     1,142        3,418        829        5,389  
  

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ 1,142      $ 8,668      $ 6,579      $ 16,389  
  

 

 

    

 

 

    

 

 

    

 

 

 

 

(1)

Reflects aggregate contractual maturities for outstanding principal as of September 30, 2024. See “Description of Material Financing” and “Note 11—Debt” to our annual financial statements, included elsewhere in this prospectus, for more information.

(2)

Excludes $3.0 billion VGLNG Series A preferred shares presented as non-controlling interest and $270 million of corresponding annual preferred dividends that are subject to adjustment and accrue indefinitely, unless optionally redeemed in accordance with their terms. See section “VGLNG Series A Preferred Shares” below and “Description of Material Financing” included elsewhere in this prospectus, for more information.

(3)

The interest rate for all VGLNG Senior Secured Notes is fixed. See “Description of Material Financing” included elsewhere in this prospectus, for more information.

For further discussion of our contractual obligations as of December 31, 2023, see “Note 15—Commitments and Contingencies” in our annual financial statements included elsewhere in this prospectus for further information.

Sources and Uses of Cash

Since our inception, we have funded our operations and capital expenditures with various forms of financing, including private placements of equity securities, project equity financings and borrowings at VGLNG and our project entities, as well as cash from our operations.

We expect to meet our short-term cash requirements using operating cash flows and available liquidity, consisting of cash and cash equivalents, restricted cash and available borrowing capacity under our existing credit facilities. Additionally, we expect to meet our long-term cash requirements by using operating cash flows and other future potential sources of liquidity, which may include debt and equity offerings by us or our subsidiaries.

The table below provides a summary of our cash and available borrowing capacity under existing credit facilities as of September 30, 2024 (in millions).

 

    September 30, 2024  
    ($ in millions)  

Cash and cash equivalents

  $ 4,562  

Restricted cash and cash equivalents

    1,073  

Available borrowing capacity under our credit facilities(1):

 

Calcasieu Pass Working Capital Facility

    301  

Plaquemines Construction Term Loan

    2,594  

Plaquemines Working Capital Facility

    919  
 

 

 

 

Total available borrowing capacity under our credit facilities

    3,814  
 

 

 

 

Total cash and available borrowing capacity

  $ 9,449  
 

 

 

 

 

(1)

Available borrowing capacity represents total borrowing capacity less outstanding borrowings and letters of credit under each of our credit facilities as of September 30, 2024.

 

139


Table of Contents

As of September 30, 2024, we had raised an aggregate of approximately $54 billion of capital. As of September 30, 2024, our subsidiaries had approximately $27.2 billion in outstanding debt, which consisted of $11.0 billion of debt incurred by VGLNG and approximately $16.2 billion in project-level debt financing. In addition, our project level equity investment subsidiaries for the Calcasieu Project, Calcasieu Holdings and Calcasieu Funding, have issued preferred units for total gross proceeds of $1.3 billion, with an aggregate liquidation preference of approximately $2.1 billion outstanding as of September 30, 2024, some of which require us to make preferential cash distributions to the holders under certain circumstances. VGLNG also issued 9.00% Series A Fixed-Rate Reset Cumulative Redeemable Perpetual Preferred Stock, with a $1,000 liquidation preference per share, or the VGLNG Series A Preferred Shares, which are entitled to preferential cash distributions, with an aggregate liquidation preference of $3.0 billion outstanding as of September 30, 2024. See “Description of Material Financing.”

In addition, we commenced production of LNG at the Calcasieu Project on a sequential basis, with each liquefaction train being brought online as it is commissioned, and we expect to do the same at our other LNG facilities. On March 1, 2022, we announced the successful loading and departure of our first cargo of LNG at the Calcasieu Project and all 18 liquefaction trains at the Calcasieu Project were capable of producing initial quantities of LNG by June 2022. As of September 30, 2024, we had loaded and sold 342 LNG commissioning cargos and earned approximately $19.6 billion in gross proceeds from such sales.

The primary use of our capital resources to date has been to fund expenses related to the development, construction, commissioning and operation of our projects and our other key, complementary assets.

We believe that our current cash and cash equivalents, borrowing capacity under our existing credit facilities, the expected proceeds from sales of LNG at our projects and the net proceeds from this offering will provide us with sufficient liquidity for at least the next 12 months, and will enable us to fund our continuing operations, our upcoming LNG tanker milestone payments, our pipeline development projects and our expected pre-FID capital expenditures with respect to the CP2 Project, the CP3 Project and the Delta Project. For further discussion of our expected proceeds from the sale of LNG refer to “Management’s Discussion and Analysis of Financial Condition and Results of Operations—Fundamentals of our Business” and “Management’s Discussion and Analysis of Financial Condition and Results of Operations—Key Factors Affecting Results of Operations.”

We anticipate that we will need substantial additional debt and equity capital to commence full construction activities and achieve COD for the CP2 Project, the CP3 Project and the Delta Project. We regularly evaluate market conditions, our capital needs, our liquidity profile, and various debt, equity and equity-linked financing alternatives at Venture Global, VGLNG, our project entities, and other subsidiaries, for opportunities to raise additional debt or equity capital and to support our growth and enhance our capital structure. The availability, timing and terms of any such additional debt and equity financing will depend on various factors, including market conditions at the time. To the extent we issue equity or equity-linked securities, there can be no assurance that any such funding will not be expensive or dilutive to stockholders.

If we are unable to obtain additional funding on a timely basis or on terms that are acceptable to us, we will have to delay, scale back or eliminate construction plans for the CP2 Project, the CP3 Project and the Delta Project, any of which could harm our business, financial condition and results of operations. Any delays in construction could prevent us from commencing operations when we anticipate and would prevent us from realizing anticipated cash flows. Our future liquidity may also be affected by the timing of construction financing availability in relation to our incurrence of construction costs and other outflows as well as the timing of our receipt of cash flows under export contracts in relation to our incurrence of project and operating expenses. Moreover, many factors (including factors beyond our control) could result in a disparity between our liquidity sources and cash needs, including factors such as construction delays and breaches of construction agreements by our contractors. After the construction period, our business may not generate sufficient cash flow from operations, currently anticipated costs may increase or future borrowings may not be available to us in amounts sufficient to enable us to pay our indebtedness or to fund our other liquidity needs, including operating expenses. See “Risk Factors.”

 

140


Table of Contents

Private Placement of VGLNG Equity Securities

Since our inception in March 2013, VGLNG has issued shares of its Series A common stock, Series B common stock and Series C common stock for aggregate net proceeds, after deducting fees and expenses, of $796 million.

Repurchases of Equity Securities

Since our inception in March 2013, and up until the Reorganization Transactions, VGLNG repurchased a total of 165,596 shares of its Series B common stock and Series C common stock for $3.0 billion. We may repurchase our capital stock from time to time. Any future determination relating to repurchases of capital stock will be made by our board of directors and will depend on a number of factors, including: our actual and projected financial condition, liquidity and results of operations; our capital levels and needs; tax considerations; any acquisitions or potential acquisitions that we may examine; statutory and regulatory prohibitions and other limitations; the terms of our existing and future indebtedness that restrict the amount of cash that we can apply to pay dividends or repurchase equity; general economic conditions; and other factors deemed relevant by the board of directors.

Credit Agreements

In February 2021, VGLNG entered into the $500 million VGLNG Corporate 2024 Term Loan. Proceeds from the issuance were used to prepay in full a previously outstanding $220 million senior secured term loan, including accrued interest, in order to fund pre-FID construction activities at the Plaquemines Project, as well as for general corporate purposes. In July 2022, VGLNG prepaid $250 million of principal outstanding under the VGLNG Corporate 2024 Term Loan.

In August 2022, VGLNG entered into the $500 million VGLNG Corporate 2025 Term Loan. Proceeds from the issuance were used to prepay the VGLNG Corporate 2024 Term Loan in full (including accrued interest and debt issuance costs). The VGLNG Corporate 2025 Term Loan accrued interest at either the adjusted term SOFR or base rate, plus an applicable margin.

In December 2022, VGLNG amended the VGLNG Corporate 2025 Term Loan to increase the total debt outstanding by $2.8 billion to a total of $3.3 billion. Proceeds from the additional borrowings were used to prepay the 2024 Convertible Notes (described below) and repurchase $1.4 billion of Series B common stock and Series C common stock shares. The remaining net proceeds were intended to be used for general corporate purposes, including to pay for certain project costs.

During the year ended December 31, 2023, we fully prepaid the $3.3 billion of principal outstanding under the VGLNG Corporate 2025 Term Loan. The prepayments were accounted for as extinguishments of the VGLNG Corporate 2025 Term Loan, resulting in a $65 million loss on financing transactions during the year ended December 31, 2023.

VG Commodities Term Loan

In August 2021, we entered into a $216 million three-year senior secured term loan facility due August 2024, or the VG Commodities Credit Agreement. Proceeds from the loans thereunder, or the VG Commodities Term Loan, were used by Legacy VG Partners to purchase certain common stock of VGLNG and for general corporate purposes. In October 2021, June 2022, and September 2023 the VG Commodities Credit Agreement was amended to incur $256 million of incremental loans in the aggregate, the proceeds of which were used for general corporate purposes, certain investments, certain distributions, and to repay certain existing debt.

In October 2023, we fully prepaid the $549 million of principal outstanding, which included certain paid-in-kind interest, under the VG Commodities Credit Agreement with a portion of the proceeds from the

 

141


Table of Contents

issuance of the VGLNG 2029 Notes and the VGLNG 2032 Notes (as defined below). The prepayments were accounted for as extinguishments of the VG Commodities Credit Agreement, resulting in a $3 million loss on financing transactions during the year ended December 31, 2023.

VGLNG Senior Secured Notes

In May 2023, VGLNG issued $2.25 billion aggregate principal amount of 8.125% Senior Secured Notes due 2028, or the VGLNG 2028 Notes, and $2.25 billion aggregate principal amount of 8.375% Senior Secured Notes due 2031, or the VGLNG 2031 Notes. The VGLNG 2028 Notes bear interest at a rate of 8.125% per annum and mature on June 1, 2028. The VGLNG 2031 Notes bear interest at a rate of 8.375% per annum and mature on June 1, 2031. The interest on each such series of notes is payable semi-annually in arrears on each June 1 and December 1.

In October 2023, VGLNG issued $2.50 billion aggregate principal amount of 9.500% Senior Secured Notes due 2029, or the VGLNG 2029 Notes, and $1.50 billion aggregate principal amount of 9.875% Senior Secured Notes due 2032, or the VGLNG 2032 Notes. In addition, in November 2023, VGLNG issued an additional $500 million aggregate principal amount of VGLNG 2029 Notes, and an additional $500 million aggregate principal amount of VGLNG 2032 Notes. The VGLNG 2029 Notes bear interest at a rate of 9.500% per annum and mature on February 1, 2029. The VGLNG 2032 Notes bear interest at 9.875% per annum and mature on February 1, 2032. The interest on each such series of notes is payable semi-annually in arrears on each February 1 and August 1, commencing on August 1, 2024.

In July 2024, VGLNG issued $1.5 billion aggregate principal amount of 7.00% Senior Secured Notes due 2030, or the VGLNG 2030 Notes. The VGLNG 2030 Notes bear interest at a rate of 7.00% per annum and mature on January 15, 2030. The interest on each such series of notes is payable semi-annually in arrears on each January 15 and July 15, commencing on January 15, 2025.

The VGLNG 2028 Notes, the VGLNG 2029 Notes, the VGLNG 2031 Notes, the VGLNG 2032 Notes and the VGLNG 2030 Notes are secured by first-priority liens in, subject to permitted liens and certain other exceptions, substantially all of our existing and future assets, if any, including our direct wholly-owned subsidiaries that directly or indirectly own the Calcasieu Project, the Plaquemines Project, the CP2 Project, the CP3 Project, the Delta Project, or any related pipeline.

VGLNG Series A Preferred Shares

In September 2024, VGLNG issued three million shares of 9.00% Series A Fixed-Rate Reset Cumulative Redeemable Perpetual Preferred Stock, with a $1,000 liquidation preference per share, or the VGLNG Series A Preferred Shares, for aggregate gross proceeds of $3.0 billion. The VGLNG Series A Preferred Shares are not convertible into any other securities and have limited voting rights.

Cumulative cash dividends on the VGLNG Series A Preferred Shares are payable semi-annually, in arrears, on each March 30 and September 30, when, as and if declared by the board of directors of VGLNG.

The dividend rate for the VGLNG Series A Preferred Shares from and including the original issue date thereof, to, but excluding, September 30, 2029, or the First Reset Date, is 9.00% per annum of the $1,000 liquidation preference per share. On and after the First Reset Date, the dividend rate on the VGLNG Series A Preferred Shares for each subsequent five-year period will be a per annum rate of the $1,000 liquidation preference equal to the applicable five-year U.S. treasury rate, plus a spread of 5.44% per annum; provided that the five-year U.S. treasury rate for each such five-year period will not be lower than 1.00%.

2024 Convertible Notes

In June 2019, VGLNG issued an aggregate of $460 million initial principal amount of the 2024 Convertible Notes. In December 2022, the 2024 Convertible Notes were prepaid in full.

 

142


Table of Contents

Project Debt and Equity Financing

In August 2019, our subsidiary, VGCP closed a $5.8 billion senior secured construction and term loan facility and a senior secured working capital facility, or collectively, the Calcasieu Pass Credit Facilities, with a group of lenders to fund the costs of developing, constructing and commissioning the Calcasieu Project. The Calcasieu Pass Credit Facilities have a final maturity date of August 19, 2026, and bear interest at SOFR plus an applicable margin. See “Description of Material Financing—Project Debt Financing—Calcasieu Project—Calcasieu Pass Credit Facilities.”

In May 2019, our subsidiaries entered into two unit purchase agreements with certain funds associated with Stonepeak Infrastructure Partners, pursuant to which Calcasieu Funding and Calcasieu Holdings, both of which are our subsidiaries, issued 9 million and 4 million preferred units, respectively, for $1.3 billion of total gross proceeds at a face value of $100 per preferred unit. These transactions closed in August, 2019 and proceeds were used to fund the equity portion of the construction costs for the Calcasieu Project. See “Description of Material Financing—Project Equity Financing.”

In August 2021, VGCP issued $2.5 billion aggregate principal amount of senior secured notes, consisting of $1.25 billion of senior secured notes due 2029, or the VGCP 2029 Notes, and $1.25 billion of senior secured notes due 2031, or the VGCP 2031 Notes. The VGCP 2029 Notes bear interest at a rate of 3.875% per annum and the VGCP 2031 Notes bear interest at a rate of 4.125% per annum, with each series of notes payable semi-annually in arrears on February 15 and August 15 of each year. The VGCP 2029 Notes will mature on August 15, 2029 and the VGCP 2031 Notes will mature on August 15, 2031. In November 2021, VGCP issued $1.25 billion aggregate principal amount of senior secured notes due 2033, or the VGCP 2033 Notes. The VGCP 2033 Notes bear interest at a rate of 3.875% per annum, payable semi-annually in arrears on May 1 and November 1 of each year. The VGCP 2033 Notes will mature on November 1, 2033. In January 2023, VGCP issued $1.0 billion aggregate principal amount of senior secured notes due 2030, or the VGCP 2030 Notes, and together with the VGCP 2029 Notes, the VGCP 2031 Notes and the VGCP 2033 Notes, the VGCP Senior Secured Notes. The VGCP 2030 Notes bear interest at a rate of 6.250% per annum, payable semi-annually in arrears on January 15 and July 15 of each year, beginning July 15, 2023. The VGCP 2030 Notes will mature on January 15, 2030. The aggregate proceeds from these issuances were used to prepay $4.2 billion outstanding under the Calcasieu Pass Credit Facilities and pay fees and expenses in connection with the offering. See “Description of Material Financing—Project Debt Financing—Calcasieu Project—VGCP Senior Secured Notes.” As of December 31, 2023, December 31, 2022 and December 31, 2021, $4.75 billion, $3.75 billion and $3.75 billion, respectively, were outstanding under the VGCP Senior Secured Notes.

In September 2021, VGCP upsized the working capital facility under the Calcasieu Pass Credit Facilities by an incremental $255 million to $555 million.

In November 2021, VGPL, as borrower, and Gator Express, as guarantor, entered into a $1.0 billion bridge loan credit facility due November 2023, or the Plaquemines Bridge Loan Facility, which was upsized to $1.4 billion in March 2022 and prepaid in May 2022. The net proceeds from the Plaquemines Bridge Loan Facility were used to fund development and construction of the Plaquemines Project prior to closing of the full project financing for Phase 1 of the Plaquemines Project.

In May 2022, VGPL, as borrower, and VGGE, as guarantor, obtained approximately $9.6 billion in project financing (consisting of an approximately $8.5 billion term loan facility and a $1.1 billion working capital revolving facility) that matures in May 2029, to fund the development and construction of Phase 1 of the Plaquemines Project. In addition, PL Funding and PL Holdings entered into two separate equity bridge credit facilities – a $2.1 billion facility, or the PL Funding Backstop Facility and a $1.45 billion facility (which was upsized by an incremental $400 million in July 2022), or the PL Holdings Credit Facility, both of which were repaid in full in 2022. A portion of the proceeds from the project financing was used to prepay the Plaquemines Bridge Loan Facility and pay fees and expenses incurred in connection with the project financing. The project

 

143


Table of Contents

financing facilities were upsized in March 2023 to fund the development and construction of Phase 2 of the Plaquemines Project. In the aggregate, the upsized project financing facilities, or the Plaquemines Credit Facilities, are comprised of an approximately $12.9 billion term loan facility and a $2.1 billion working capital revolving facility. In connection with the upsize, PL Holdings entered into the Plaquemines Equity Bridge Facility, a new approximately $1.7 billion secured credit facility equity bridge credit facility to fund a portion of project costs for the Plaquemines Project. The remaining proceeds from the project financing and the outstanding PL Holdings financing will be used to fund the costs of financing, developing, constructing, and commissioning the Plaquemines Project. In July 2024, we prepaid the remaining outstanding amount of the Plaquemines Equity Bridge Facility in full using proceeds from the VGLNG 2030 Notes.

For further information on the foregoing financings, see “Description of Material Financing.”

Cash Flows

Nine Months Ended September 30, 2024 Compared to Nine Months Ended September 30, 2023

The following table shows a summary of our cash flows for the periods indicated:

 

     Nine months ended
September 30,
     Change  
      2024        2023       ($)      (%)  
     ($ in millions)  

Net cash from operating activities

   $ 1,476      $ 3,957      $ (2,481      (63 )% 

Net cash used by investing activities

     (10,436      (5,044      (5,392      107

Net cash from financing activities

     8,723        1,793        6,930        NM  

 

NM Percentage not meaningful.

Operating activities

Net cash from operating activities during the nine months ended September 30, 2024 was $1.5 billion, a $2.5 billion, or 63%, decrease from $4.0 billion during the nine months ended September 30, 2023. The net decrease in cash inflows was primarily due to:

 

   

a decrease of $2.6 billion of cash received for the sale of LNG at the Calcasieu Pass Project; and

 

   

an increase of $375 million of cash paid for operating expenses.

These decreases in net cash inflows from operating activities were partially offset by:

 

   

a decrease of $370 million of cash paid for costs of sales, largely for the purchase of natural gas at the Calcasieu Pass Project;

 

   

a decrease of $99 million of cash paid for income taxes; and

 

   

an increase of $95 million of cash received from interest income.

Investing activities

Net cash used by investing activities during the nine months ended September 30, 2024 was $10.4 billion, a $5.4 billion, or 107%, increase from $5.0 billion during the nine months ended September 30, 2023. The net increase in cash outflows was primarily due to an increase in cash used for purchases of property, plant and equipment of $5.5 billion primarily related to an increase in cash paid for construction of $3.1 billion at the Plaquemines Project and cash paid for capitalizable equipment and materials of $1.5 billion at the CP2 LNG Project.

 

144


Table of Contents

Financing activities

Net cash from financing activities during the nine months ended September 30, 2024 was $8.7 billion, a $6.9 billion increase from $1.8 billion during the nine months ended September 30, 2023. The net increase in cash inflows was primarily due to:

 

   

a decrease in principal payments on debt of $4.2 billion due to $859 million of payments during the nine months ended September 30, 2024 comprised of:

 

   

the prepayments of $727 million of the PL Holdings Credit Facility; and

 

   

the repayments of $132 million of the Calcasieu Pass Credit Facilities.

This compares to $5.1 billion of principal payments on debt during the nine months ended September 30, 2023, comprised of:

 

   

the prepayment of $3.3 billion of the VGLNG Corporate 2025 Term Loan;

 

   

the prepayments of $1.1 billion of the Calcasieu Pass Credit Facilities; and

 

   

the prepayments of $700 million of the PL Holdings Credit Facility;

 

   

an increase in proceeds from project credit facilities of $3.6 billion due to proceeds from the Plaquemines Credit Facility of $5.4 billion during the nine months ended September 30, 2024 as compared to proceeds of $1.9 billion during the same period in 2023;

 

   

proceeds from issuance of VGLNG Series A Preferred Shares of $3.0 billion during the nine months ended September 30, 2024, with no similar activity during the same period in 2023;

 

   

the repurchase of non-controlling interests (VGLNG common stock) of $1.6 billion during the nine months ended September 30, 2023, with no similar activity during the same period in 2024; and

 

   

a decrease in payments of financing and debt issuance costs of $363 million due to $95 million of payments during the nine months ended September 30, 2024, as compared to payments of $458 million during the same period in 2023.

These net increases to cash inflows were partially offset by a decrease in proceeds from the issuance of debt of $5.7 billion due to $1.6 billion of proceeds during the nine months ended September 30, 2024 comprised of:

 

   

$1.5 billion from the issuance of the VGLNG 2030 Notes.

 

   

$84 million from the issuance of other fixed rate debt.

This compares to $7.3 billion of proceeds during the nine months ended September 30, 2023 of:

 

   

$4.5 billion from the issuance of the VGLNG 2028 Notes and the VGLNG 2031 Notes;

 

   

$1.7 billion from the issuance of the PL Holdings Credit Facility in connection with FID of Phase 2 of the Plaquemines Project; and

 

   

$1.0 billion from the issuance of the VGCP 2030 Notes.

 

145


Table of Contents

Year Ended December 31, 2023 Compared to Year Ended December 31, 2022

The following table shows a summary of our cash flows for the periods indicated:

 

     Years ended December 31,      Change  
      2023        2022       ($)      (%)  
     ($ in millions)  

Net cash from operating activities

   $ 4,550      $ 3,702      $ 848        23

Net cash used by investing activities

     (8,725      (2,900      (5,825      201

Net cash from financing activities

     7,635        235        7,400        NM  

 

NM Percentage not meaningful.

Operating Activities

Net cash from operating activities was $4.6 billion during the year ended December 31, 2023, a $848 million, or 23%, increase from $3.7 billion during the year ended December 31, 2022. The net increase in cash inflows was primarily due to:

 

   

an increase of $1.4 billion of cash proceeds received from test LNG sales produced by the Calcasieu Pass Project assets that were placed in service from an accounting perspective between April and August 2022;

 

   

a $208 million favorable change in cash from the settlement of interest rate swaps due to $203 million in net cash received during the year ended December 31, 2023 as compared to $5 million net cash paid to settle interest rate swaps during the year ended December 31, 2022; and

 

   

an increase of $149 million of cash received from interest income due to larger average cash balances and higher interest rates during the year ended December 31, 2023 as compared to the year ended December 31, 2022.

These increases in cash inflows were partially offset by:

 

   

an increase of $610 million of cash paid for operating expenses primarily due to an increase in development and pre-construction activities related to the CP2 LNG Project that were not capitalizable and operating activities related to the Calcasieu Pass Project, partially offset by a decrease in development activities related to the Plaquemines Project primarily due to it being deemed probable in March 2022, and the costs to develop the facility subsequently being capitalized;

 

   

a net increase of $138 million of cash paid for non-capitalized interest and commitment fees comprised of $129 million at the Calcasieu Pass Project and $18 million at Corporate, other and eliminations, offset by a decrease of $10 million at the Plaquemines Project; and

 

   

an increase of $128 million of cash paid for income taxes with no similar material activity during the year ended December 31, 2022.

Investing Activities

Net cash used by investing activities was $8.7 billion during the year ended December 31, 2023, a $5.8 billion, or 201%, increase from $2.9 billion during the year ended December 31, 2022. The net increase in cash outflows was primarily due to:

 

   

an increase in cash used for purchases of property, plant and equipment of $3.5 billion related to:

 

   

an increase in cash paid for construction of the Plaquemines Project of $3.5 billion for costs incurred after the project was deemed probable in March of 2022;

 

   

an increase of $915 million primarily due to advanced equipment payments related to the CP2 LNG Project; and

 

146


Table of Contents
   

an increase of $600 million due to advanced equipment payments and capitalized interest payments at Corporate, other and eliminations.

These increases were partially offset by a decrease at the Calcasieu Pass Project of $1.6 billion since assets were placed in service from an accounting perspective in 2022;

 

   

a decrease in cash proceeds of $1.8 billion from test LNG sales, which was offset against construction in progress, during the year ended December 31, 2022, with no similar cash inflows during the year ended December 31, 2023; and

 

   

an increase in cash outflows of $539 million to purchase equity investments in Project Kagami 1 Limited and Project Kagami 2 Limited, or together, the Kagami Companies, and Astra 5 Limited and Astra 8 Limited, or together, the Astra Companies, for the ultimate acquisition of four LNG tankers.

Financing Activities

Net cash from financing activities was $7.6 billion during the year ended December 31, 2023, a $7.4 billion increase from $235 million during the year ended December 31, 2022. The net increase in cash inflows was primarily due to:

 

   

an increase in proceeds from the issuance of debt of $6.3 billion due to $12.3 billion of proceeds from debt issuances during the year ended December 31, 2023, comprised primarily of:

 

   

proceeds of $9.5 billion from the issuance of the VGLNG Senior Secured Notes;

 

   

proceeds of $1.7 billion from the issuance of the Plaquemines Equity Bridge Facility in connection with FID for Phase 2 of the Plaquemines Project;

 

   

proceeds of $1.0 billion from the issuance of the 2030 VGCP Senior Secured Notes; and

 

   

proceeds of $115 million from the upsizing of the VG Commodities Term Loan.

These compare to $6.0 billion of proceeds from debt issuances during the year ended December 31, 2022, comprised primarily of:

 

   

proceeds of $3.2 billion due to the refinancing of the VGLNG Corporate 2025 Term Loan;

 

   

proceeds of $2.4 billion from debt associated with the Plaquemines Project;

 

   

an increase in proceeds from the project credit facilities of $2.2 billion due to an increase in proceeds from the Plaquemines Credit Facilities of $2.8 billion, partially offset by a decrease in proceeds from the Calcasieu Pass Credit Facilities of $626 million; and

 

   

a decrease in payments of financing and debt issuance costs of $295 million due to $591 million of payments during the year ended December 31, 2023 compared to debt issuance costs of $886 million during the year ended December 31, 2022.

These net increases to cash inflows were partially offset by:

 

   

an increase in principal payments on debt of $875 million due to $5.9 billion of repayments during the year ended December 31, 2023 comprised of:

 

   

the prepayment of $3.3 billion of the VGLNG Corporate 2025 Term Loan;

 

   

the repayments of $1.1 billion of the Calcasieu Pass Credit Facilities;

 

   

the prepayments of $938 million of the Plaquemines Equity Bridge Facility; and

 

   

the prepayment of $549 million of the VG Commodities Term Loan.

 

147


Table of Contents

These compare to $5.0 billion of principal payments on debt during the year ended December 31, 2022, comprised of:

 

   

the repayment of $3.4 billion for debt associated with the Plaquemines Project;

 

   

the repayment of $863 million for the 2024 Convertible Notes and corresponding embedded derivative liability;

 

   

the repayment of $385 million due to the refinancing of the VGLNG Corporate 2025 Term Loan;

 

   

the repayment of $95 million of the Calcasieu Pass Working Capital Facility; and

 

   

an increase in purchases of non-controlling interests of $147 million during the year ended December 31, 2023 as compared to the same period in 2022.

Year Ended December 31, 2022 Compared to Year Ended December 31, 2021

The following table shows a summary of our cash flows for the periods indicated:

 

     Years ended December 31,      Change  
      2022        2021       ($)      (%)  
     ($ in millions)  

Net cash from (used by) operating activities

   $ 3,702      $ (503    $ 4,205        NM  

Net cash used by investing activities

     (2,900      (2,078      (822      40

Net cash from financing activities

     235        3,623        (3,388      (94 )% 

 

NM Percentage not meaningful.

Operating Activities

Net cash from operating activities was $3.7 billion during the year ended December 31, 2022, compared to net cash used by operating activities of $503 million during the year ended December 31, 2021. The increase of $4.2 billion was primarily related to

 

   

an increase of $6.4 billion of cash received for the sale of LNG produced by the Calcasieu Pass Project assets that were placed in service from an accounting perspective between April and August 2022; and

 

   

a reduction of $226 million of cash paid to settle interest rate swaps that are not designated as cash flow hedges during the year ended December 31, 2022, compared to the year ended December 31, 2021.

These increases to operating cash inflows were partially offset by:

 

   

an increase of $1.8 billion of cash paid for costs of sales, largely for the purchase of natural gas, at the Calcasieu Pass Project since assets were placed in service from an accounting perspective in 2022;

 

   

an increase of $342 million of cash paid for operating, development and general and administrative expenses primarily due to increased early construction-related activity at the Plaquemines Project in 2022, prior to the project being deemed probable, and increased operational activity at the Calcasieu Pass Project in support of LNG production during the year ended December 31, 2022, compared to lower pre-production operational support, a portion of which was capitalized, during the year ended December 31, 2021; and

 

   

an increase of $265 million of cash paid for non-capitalized interest and commitment fees primarily comprised of $105 million at the Calcasieu Pass Project, $104 million at the Plaquemines Project and $56 million at Corporate, other and eliminations.

 

148


Table of Contents

Investing Activities

Our investing activities consist primarily of capital expenditures and the purchase, sale and maturity of restricted and unrestricted investments.

Net cash used by investing activities during the year ended December 31, 2022 and 2021 was $2.9 billion and $2.1 billion, respectively. The increase in cash outflows of $822 million, or 40%, was primarily due to

 

   

an increase in cash used for purchases of property, plant and equipment of $2.6 billion related to

 

   

an increase in cash paid for construction of the Plaquemines Project of $2.9 billion for costs incurred after the project was deemed probable in March of 2022, partially offset by

 

   

a decrease at the Calcasieu Pass Project of $304 million and an increase in cash paid for deposits for construction equipment of $26 million.

These increases in net cash used by investing activities were partially offset by cash proceeds of $1.8 billion from test LNG sales, which was offset against construction in progress during the year ended December 31, 2022.

Financing Activities

Net cash from financing activities during the year ended December 31, 2022 and 2021 was $235 million and $3.6 billion, respectively. The net decrease in cash inflows of $3.4 billion, or 94%, was primarily due to:

 

   

an increase in debt repayments during the year ended December 31, 2022 of $1.8 billion primarily due to:

 

   

the repayment of $3.4 billion at Plaquemines for the PL Holdings Credit Facility, the PL Funding Backstop Facility and the Plaquemines Bridge Loan Facility;

 

   

the repayment of $863 million for the 2024 Convertible Notes and its corresponding embedded derivative liability;

 

   

the repayment of $735 million due to the refinancing of the VGLNG Corporate 2024 Term Loan and the VGLNG Corporate 2025 Term Loan; and

 

   

the repayment of $95 million under the Calcasieu Pass Working Capital Facility in year ended December 31, 2022.

These compare to:

 

   

the debt prepayments of $3.2 billion related to the Calcasieu Pass Credit Facilities and $100 million of the VGLNG Corporate 2024 Term Loan during the year ended December 31, 2021;

 

   

purchases of non-controlling interests of $1.4 billion during the year ended December 31, 2022, compared to $185 million during the year ended December 31, 2021;

 

   

a decrease in proceeds from project credit facilities of $680 million due to a $1.7 billion decrease in proceeds under the Calcasieu Pass Credit Facilities, which was fully drawn as of May 2022, partially offset by a $1.1 billion increase in proceeds drawn under the Plaquemines Credit Facilities, which was issued in 2022; and

 

   

an increase in payments for debt issuance costs of $753 million during the year ended December 31, 2022, primarily related to issuance costs for Phase 1 of the Plaquemines Project, fees incurred for the prepayment of the 2024 Convertible Notes, and issuance costs incurred to increase the VGLNG Corporate 2025 Term Loan, partially offset by prior year debt issuance costs associated with the VGCP Senior Secured Notes.

 

149


Table of Contents

These increases in cash outflows were partially offset by:

 

   

an increase in proceeds from the issuance of debt during the year ended December 31, 2022 of $578 million due to $6.0 billion of proceeds from debt issuances in 2022 comprised of:

 

   

the proceeds of $3.5 billion due to the refinancing of the VGLNG Corporate 2024 Term Loan and VGLNG Corporate 2025 Term Loan;

 

   

the proceeds of $2.4 billion due to the $1.9 billion issuance and draw on the PL Holdings Credit Facility, the $400 million increase of the Plaquemines Bridge Loan Facility, and the $100 million issuance and draw on the PL Funding Backstop Facility; and

 

   

the proceeds of $89 million due to the refinancing of the VG Commodities Term Loan during the year ended December 31, 2022.

These compare to $5.4 billion of proceeds from debt issuances in 2021 comprised of:

 

   

proceeds from the issuance of $3.8 billion of the VGCP Senior Secured Notes,

 

   

the issuance of the $1.0 billion Plaquemines Bridge Loan Facility,

 

   

the $380 million upsizing of the VGLNG Corporate 2024 Term Loan, and

 

   

the issuance of the $266 million VG Commodities Term Loan during the year ended December 31, 2021;

 

   

a decrease in net cash used in the settlement of derivatives of $273 million due to the partial settlement of the interest rate swaps related to the Calcasieu Project with a financing component during the year ended December 31, 2021, with no similar settlement activity in the current year; and

 

   

a decrease in cash used for financed purchases of property, plant and equipment of $200 million during the year ended December 31, 2022, compared to the year ended December 31, 2021.

Critical Accounting Policies and Estimates

Use of Estimates

The preparation of the consolidated financial statements and interim condensed consolidated financial statements in conformity with GAAP requires management to make estimates and assumptions that affect the amounts reported in the consolidated financial statements and accompanying notes. We evaluate our assumptions on an ongoing basis. The accounting policies and estimates discussed below are considered by our management to be critical to an understanding of our financial statements as their application requires the most significant judgments from management in estimating matters for financial reporting that are inherently uncertain. While we believe the estimates and assumptions used in the preparation of the consolidated financial statements are appropriate, actual results could differ from these estimates.

Revenue from Contracts with Customers

The transaction price defined in our contracts for the sale of LNG to third-party customers include both fixed and variable components including variable consideration for contingent penalties or fees which may be due from the Company and could result in the significant reversal of revenue. Estimates for penalties or fees are recognized as a reduction to the transaction price until the future significant reversal of revenue is no longer probable of occurring or once the uncertainty is resolved. For further discussion, see “Note 4 – Revenue from Contracts with Customers” to our annual financial statements, included elsewhere in this prospectus, for more information.

 

150


Table of Contents

Critical Accounting Policies

Revenue Recognition

The majority of our nameplate capacity produced at the Calcasieu Project and the Plaquemines Project after COD will be sold under long-term 20-year SPAs. We aim to market and sell the expected nameplate capacity at our subsequent projects under a combination of long-term 20-year SPAs as well as short- and medium-term contracts to optimize the average fixed facility charge across our SPAs. Delivery under these post-COD SPAs commences upon achieving COD of the respective LNG facilities, which has not yet occurred for any of our projects. LNG produced prior to an LNG facility achieving COD is sold to various customers under master SPAs, either as single cargos or as multiple cargos to be loaded over a period of time, and are based on spot and/or forward prices at the time of execution.

We recognize revenue when we transfer control of promised goods or services to our customers in an amount that reflects the consideration we expect to be entitled to receive in exchange for those goods or services. Revenue from the sale of LNG is recognized at the point in time when the LNG is delivered to the customer at the agreed upon LNG terminal which is the point when legal title, physical possession and the risks and rewards of ownership transfer to the customer. Each individual molecule of LNG is viewed as a separate performance obligation. The stated contract price, including both fixed and variable components, is representative of the stand-alone selling price for LNG at the time the contract was negotiated. Sales of LNG commissioning cargos and under our SPAs include variable consideration for contingent penalties or fees which may be due from the Company, and if so, could result in the significant reversal of revenue. Estimates for penalties or fees are recognized as a reduction to the transaction price until the future significant reversal of revenue is no longer probable of occurring or once the uncertainty is resolved. Payment terms are within 30 days after the LNG is delivered.

Net proceeds from generation and delivery of test LNG are determined based on estimates of LNG production generated from commissioning activities and recognized as a reduction to the cost basis of construction in progress until assets are placed in service from an accounting perspective.

Capitalization of Development and Construction Costs

Generally, the costs incurred to develop our LNG facilities are treated as development expenses until construction of the relevant project is considered probable. Costs primarily include professional fees associated with front-end engineering and design work, costs of securing necessary regulatory approvals, and other preliminary investigation and development activities related to our projects. In assessing probability, we consider whether: (i) management has committed to funding construction of the LNG project, (ii) financing for the project is available and (iii) the ability exists to meet the necessary local and other governmental regulations. Certain costs are capitalized prior to a project meeting the criteria otherwise necessary for capitalization, which requires judgment and is based upon our assessment of our ability to realize the future benefits associated with these assets. For example, we have capitalized the cost of equipment and materials that are expected to be used on projects that are not yet probable when the equipment and materials have alternative use and are otherwise recoverable in other projects or for resale. Our construction and equipment supplier arrangements also contain various terms including retainage, performance bonuses, and liquidated damages, that impact the amount and timing of the recognition of the related costs. We capitalized costs of $30.7 billion and $19.4 billion into property, plant, and equipment, net as of September 30, 2024 and December 31, 2023, respectively, and recognized development expenses of $511 million, $490 million, and $311 million during the nine months ended September 30, 2024 and the years ended December 31, 2023, and 2022, respectively. For further discussion, see “Note 5 – Property, Plant and Equipment” to our interim condensed consolidated financials and “Note 6 – Property, Plant and Equipment” to our annual financial statements, each included elsewhere in this prospectus, for more information.

 

151


Table of Contents

Derivative Instruments

We reflect all contracts that meet the definition of a derivative, except those designated and qualifying as normal purchase or normal sale, as either assets or liabilities on the Consolidated Balance Sheets at fair value. Changes in the fair value of derivative instruments are recognized in earnings, unless we elect to apply hedge accounting and meet the specified criteria in ASC 815, Derivatives and Hedging. We designate derivatives instruments based on all available facts and circumstances.

We enter into interest rate swap agreements to mitigate volatility arising from changes in interest rates. We do not utilize derivatives for trading or speculative purposes. Derivative instruments are recognized at their fair values on the Consolidated Balance Sheets. Changes in fair value of derivative instruments designated as cash flow hedges are recognized in accumulated other comprehensive income or loss, or AOCL, until the hedged transaction affects earnings, at which time the deferred gains and losses are reclassified to earnings. Cash flows associated with derivatives hedging capitalized interest and designated as cash flow hedges are classified as investing activities in the Consolidated Statements of Cash Flows unless the derivatives contain an other-than-insignificant financing element at inception, in which case the associated cash flows are classified as financing activities. Cash flows of our derivatives which are not designated as hedging relationships are classified as operating activities in the Consolidated Statements of Cash Flows. Derivative assets and liabilities are presented net on the Consolidated Balance Sheets when a legally enforceable master netting arrangement exists with the counterparty.

We discontinue hedge accounting on a prospective basis if the derivative is no longer expected to be highly effective as a hedge, if the hedged transaction is no longer probable of occurring, or if we de-designate the instrument as a cash flow hedge. Any gain or loss in AOCL at the time of de-designation is reclassified into earnings in the same period the hedged transaction affects earnings unless the underlying hedged transaction is probable of not occurring, in which case, any gain or loss in AOCL is reclassified into earnings immediately. For further discussion, see “Note 12 – Derivatives” to our annual financial statements, included elsewhere in this prospectus, for more information.

Income Taxes

We account for U.S. federal, state and foreign income taxes under the asset and liability method, which requires the recognition of deferred income tax assets and liabilities for the expected future tax consequences of events that have been included in the financial statements. Under this method, we determine income tax assets and liabilities based on the differences between the financial statement and income tax basis for assets and liabilities using the enacted statutory tax rates in effect for the year in which the differences are expected to reverse. The effect of a change in tax rate on deferred income tax assets and liabilities is recognized in income in the period that includes the enactment date.

A valuation allowance is provided for deferred income taxes if it is more-likely-than-not these items will either expire before we are able to realize their benefits or if future deductibility is uncertain. Additionally, we evaluate tax positions under a more-likely-than-not recognition threshold and measurement analysis before the positions are recognized for financial statement reporting.

Our accounting policy for releasing the income tax effects from AOCL occurs on a portfolio basis. For further discussion, see “Note 14 – Income Taxes” to our annual financial statements, included elsewhere in this prospectus, for more information.

 

152


Table of Contents

Quantitative and Qualitative Disclosure About Market Risk

Interest Rate Risk

As of December 31, 2023, our exposure to market risk for changes in interest rates related primarily to the Calcasieu Pass Credit Facilities, the Plaquemines Credit Facilities and our investment portfolio. The Calcasieu Pass Credit Facilities and the Plaquemines Credit Facilities accrued interest at term SOFR, plus an applicable margin. Therefore, fluctuations in interest rates will impact our consolidated financial statements. A rising interest rate environment will increase the amount of interest paid on these loans. We entered into interest rate hedge arrangements to manage our interest rate exposure under the Calcasieu Pass Credit Facilities, and Plaquemines Credit Facilities. As of September 30, 2024 and December 31, 2023, we had hedges targeting 97% of our variable rate debt for the Calcasieu Project and 80% of our variable rate debt for both phases of the Plaquemines Project. For the nine months ended September 30, 2024 and the year ended December 31, 2023, a hypothetical 100 basis point increase in interest rates would have increased our interest expense by $15.5 million and $12.2 million, respectively.

The fair value of our credit facilities will generally fluctuate with movements of interest rates, increasing in periods of declining rates of interest and declining in periods of increasing rates of interest. A hypothetical 100 basis point increase or decrease in interest rates would not have had a material impact on the fair value of our credit facilities as of September 30, 2024, December 31, 2023, December 31, 2022 and December 31, 2021.

The primary objective of our investment activities is to preserve our capital for the purpose of funding our operations. We do not enter into investments for trading or speculative purposes. We generally invest our cash in investments with short maturities or with frequent interest reset terms. Accordingly, our interest income fluctuates with short-term market conditions. As of September 30, 2024, December 31, 2023 and December 31, 2022, our investment portfolio consisted of $1.4 billion, $3.4 billion and $378 million, respectively. Due to the short-term nature of our investment portfolio, our exposure to interest rate risk is minimal.

To the extent we utilize additional debt financing, we may incur fixed or floating rate debt or a combination thereof. We will have exposure to changes in interest rates until such time as the interest rates on any such instruments are determined. We will also have exposure to changes in interest rates with respect to any floating rate debt we incur, unless we enter into interest rate hedges with respect to any such exposure.

Commodity Price Risk

We face commodity price exposure in connection with the construction of our projects, and we expect to also face commodity price exposure during operation of our projects, which we seek to mitigate through certain pricing mechanisms in our SPAs.

In connection with the construction of our projects, our exposure to commodity price risk relates primarily to the price at which we are able to execute a reimbursable EPC contract with target price that considers anticipated inflation and models financed contingency to absorb commodity pricing pressure, labor cost increases, and cost overruns for the construction of the relevant project. We expect that price will fluctuate with changes in prices of the relevant commodities to be utilized in the construction of the relevant project, which will primarily be steel, aluminum, nickel, concrete and diesel fuel. In addition, we may be exposed to commodity price risk even after we execute the EPC contract and other key owner furnished equipment contracts for the relevant project, up until the point in time that commodity pricing is locked in and / or procured. For example, for our future projects we may be exposed to changes in prices of such commodities if the relevant project is delayed in issuing notice to proceed (or the equivalent) and that delay results in adjustments to the contract price, or if the scope of the project changes subsequent to execution of the contract. We anticipate that the commissioning cargo proceeds expected to be generated by each project will provide additional contingency that is held at the project-level until certain production milestones are achieved and contingency utilization is replenished.

 

153


Table of Contents

Following the commencement of operations at our projects, our exposure to market risk for changes in commodity prices will relate primarily to the margin we charge our export customers for feed gas under SPAs. Export customers under our existing SPAs will pay a fee equal to a fixed facility charge (which includes a CPI-linked component) per MMBtu, plus a variable commodity charge per MMBtu, in an amount equal to, depending on the applicable SPA, 115% or more of the Henry Hub gas price, which is intended to cover the price of the feed gas and gas transportation costs and is also intended to cover certain of our operating expenses and partially adjust for inflation. We anticipate that any additional LNG contracts we enter into in the future will similarly require our export customers to pay a fixed facility charge per MMBtu, plus a variable commodity charge per MMBtu, in an amount equal to or higher than 115% of the Henry Hub gas price. As a result, changes in the price of feed gas will impact our operating margins. In addition, there may be differences between the actual price we pay for feed gas and the Henry Hub gas price used to calculate the variable commodity charges under the relevant LNG sales contract. Our operating margins would be affected by any such differences.

 

154


Table of Contents

LNG INDUSTRY OVERVIEW

This section includes industry and market data, including our general expectations and market position, market opportunity and market size, as well as future growth rates relating to our market opportunity and the industry and markets in which we operate, that is based on industry publications and other published industry sources prepared by third parties. Although we believe the industry and market data to be reliable as of the date of this prospectus, this information could prove to be inaccurate. Moreover, projections, assumptions and estimates of the future performance of the industry in which we operate, including future growth rates and related estimates, forecasts and projections relating to the industry in which we operate and our market position, market opportunity and market size, are prospective in nature. Any such projections, assumptions and estimates are necessarily subject to a high degree of uncertainty and risk due to a variety of factors, including those described in the sections captioned “Risk Factors” and “Special Note Regarding Forward-Looking Statements” elsewhere in this prospectus. These and other factors could cause any such projections, assumptions and estimates, to differ materially from those expressed in the projections, assumptions and estimates made by third parties and by us and you are cautioned not to give undue weight to such projections, assumptions and estimates. See “Market and Industry Data” for further information and important limitations and uncertainties regarding the industry and market data we present.

Introduction to Natural Gas and LNG

Natural gas is an abundant, cost-effective, and reliable energy source with lower emissions than traditional oil and coal that we believe will play a critical role in supporting the growing global economy for decades to come. Natural gas provides several key advantages over other energy sources:

 

  (i)

Abundant: There are an estimated 7,299 trillion cubic feet, or Tcf, of proven natural gas reserves globally, of which approximately 691 Tcf are located in the U.S., making it one of the largest resources in the world. This abundance ensures long-term availability, encouraging investments in the infrastructure required to extract, transport, and use natural gas

 

  (ii)

Cost Effective: Recent advancements in extraction technologies have significantly boosted natural gas extraction productivity and lowered costs. On average, the levelized cost of electricity from gas is $76/MWh, significantly cheaper than coal at $118/MWh and nuclear at $182/MWh

 

  (iii)

Lower Emissions: When used in power generation, natural gas produces 30-60% less CO2 than traditional oil and coal. Natural gas combustion also releases minimal sulfur dioxide and particulate matter, issuing far less air pollution than other traditional fuel sources

 

  (iv)

Reliable: Unlike intermittent renewable sources like wind and solar, natural gas-powered generation offers a reliable and steady energy output that can quickly ramp up and cycle to meet rising electricity demand during peak periods or emergencies, as well as balance and contribute to the baseload voltage stability of the power grid

As the global economy continues to grow and the need for reliable, stable electricity generation increases – whether it be from data center demand in highly-developed countries or industrial growth and urbanization in developing regions – the availability, safety, and reliability of natural gas makes it a critical energy source and a key driver towards a cleaner, more sustainable future.

While natural gas is abundant and widely used as a fuel source, global access is challenged by logistic and geographic limitations. Natural gas in its gaseous state can only be transported at scale by pipelines or trucks, and reserves are geographically concentrated in North America, the Middle East, Australia and Russia. Regions without indigenous natural gas supply and limited pipeline connectivity to supply sources, such as Europe and Asia, face significant challenges accessing the fuel. Beginning in the 1970’s, the LNG industry has grown dramatically as an efficient and affordable means to supply natural gas to those regions otherwise lacking access to natural gas.

 

155


Table of Contents

The process of liquefaction facilitates the compression, transportation, and storage of natural gas. Through this proven process, natural gas is cooled down to -260° Fahrenheit (-162° Celsius) transforming it into a liquid state. Liquefied natural gas, occupies just 1/600th of the original volume, making it easier and cheaper to store and transport large quantities over long distances onboard LNG carriers. The capacity of large LNG carriers varies, with modern vessels typically able to transport between 120,000 to 260,000 cubic meters of LNG per cargo. Each cargo represents enough energy to power up to 70,000 homes for one year. Once the LNG reaches its destination, it undergoes regasification, a process where the LNG is warmed back to its gaseous state. The gas is then fed into pipelines or trucks for distribution to meet local industrial and residential energy demand.

Natural gas is a versatile energy source and is widely used across industrial, commercial, and residential sectors. Its primary applications include electricity generation, heating, serving as feedstock to produce various chemical compounds (plastics, resins, fertilizers, etc.), and fuel for heavy duty vehicles and ships. Natural gas consumption is projected to rise in the coming decades, propelled by a shift away from coal and other carbon intensive fuels, the growing trend toward electrification, and global population and economic growth.

LNG Market

LNG is not traded or sold based on a uniform international price or index. Prices vary significantly across regions due to several factors, including local and global supply-demand dynamics, seasonality, production costs, shipping and transportation costs and geopolitical influences. The profit margin for U.S. LNG producers on exports is typically determined by the difference between the prevailing LNG reference price and the associated local natural gas and liquefaction costs. These reference prices may be set by the spot market or secured through both short- and long-term contractual agreements.

LNG Pricing Composition

The formation of LNG prices is shaped by multiple factors, including:

 

  (i)

Contract Type: This encompasses long-term contracts (typically ranging from four to twenty years), short-term contracts (four years or less), and spot market contracts (for delivery within three months of the transaction date)

 

  (ii)

Benchmark Reference Price: Such as the price of crude oil or natural gas

 

  (iii)

Price Indexation or Escalation Clauses: These may include indexation to inflation or fixed price escalation

 

  (iv)

Commercial Structure: For example, merchant arrangement or tolling arrangement

 

  (v)

Shipping Arrangement: Such as Delivery Ex-Ship (DES), Delivered at Place Unloaded (DPU), or Free-On-Board (FOB)

The specific terms of supply negotiated by the parties involved can materially alter both the contract price formation and the agreed-upon pricing levels.

In a DPU arrangement, the seller assumes the full cost and risk involved in transporting goods to a buyer. In an FOB arrangement, the buyer is responsible for transporting the product and assumes all risk once the seller delivers the product.

Benchmark Reference Price

Historical long-term LNG contracts were predominately indexed to the price of certain alternative fuels such as crude oil. Oil-linked LNG pricing remains widespread outside of the U.S., particularly in the Middle East and Asia, representing approximately 30% of global LNG trade pricing in 2022. Under this pricing construct, LNG is priced as a “percent of” or “slope to” oil. These contracts have been typically priced at around 12% to 15% of Brent. However, as U.S. LNG has become more prominent, oil-linked LNG pricing has become less dominant.

 

156


Table of Contents

Before the rise of U.S. LNG, most LNG-exporting countries lacked a liquid and transparent natural gas market to use as a pricing benchmark, leading to the reliance on oil prices. U.S. LNG introduced a shift in this dynamic due to the existence of an established natural gas trading hub, Henry Hub, or HH. This shift introduces several key benefits:

 

  (i)

Market Reflectivity: HH pricing closely mirrors U.S. natural gas market fundamentals, providing a more accurate reflection of supply and demand conditions

 

  (ii)

Price Stability: Gas-linked pricing tends to exhibit less volatility compared to oil-linked pricing, offering greater price stability for both buyers and sellers, which enhances long-term contract predictability

 

  (iii)

Transparency: As U.S. natural gas and LNG have gained prominence in international energy markets, HH prices have become more widely reported, enhancing market transparency and enabling more informed decision-making

International Liquid Traded Markets

Aside from HH, the global LNG market is underpinned by several key pricing benchmarks that reflect regional supply and demand dynamics. Among the most prominent are the European Title Transfer Facility, or TTF, the Japan-Korea Marker, or JKM, and the Gulf Coast Marker, or GCM, which reflect the regional natural gas spot price. For volumes shipped to Europe, the price used is typically TTF, and for volumes destined for Asia, the referenced price is typically JKM.

 

  (i)

TTF: The virtual trading point for natural gas in the Netherlands. TTF reflects the price of gas for immediate delivery (spot) and is widely used as a benchmark for natural gas trading and contracts across Europe. The TTF price is crucial for assessing market conditions and is indicative of gas supply and demand in the European market

 

  (ii)

JKM: The virtual trading point for natural gas in Japan and South Korea. Asian markets, particularly Japan and South Korea, have traditionally paid high prices for LNG due to the higher cost of alternative energy sources and strong demand for clean energy in these regions. JKM is widely used by traders, producers, and consumers to gauge LNG pricing and trends in the Asia-Pacific region

 

  (iii)

GCM: A benchmark closely linked to U.S. LNG export activity. GCM reflects LNG bids, offers and transactions on an FOB U.S. basis, normalized to the U.S. Gulf Coast. These prices are quoted on a USD/MMBtu basis. Historical GCM pricing trends have closely followed those of TTF and JKM, just at a lower absolute dollar value. Although cited less frequently than TTF or JKM, the GCM pricing index has become more popular over time as the Gulf Coast LNG sector has developed

Spot Market

Significant growth in the LNG spot market over the past decade has transformed the global LNG landscape. Unlike long-term contracts which span 4 to 25 years and involve fixed pricing mechanisms, the spot market involves the purchase and sale of LNG cargos for near-term delivery, usually within a few months. Producers can sell into these higher-priced and shorter duration markets, with the lowest-cost producers realizing higher margins. This market has introduced greater flexibility, liquidity, and price transparency to the LNG industry.

Cargos sold into the spot market follow different pricing mechanisms relative to traditional tolling or long-term agreements and fluctuate based on current supply and demand. LNG is typically sold in the spot market at international pricing, with the profit that the LNG supplier realizes being the “net spread” (measured in $/MMBtu). Net spreads are determined by subtracting all fixed and variable costs associated with producing (or purchasing) and delivering LNG to the destination market—including pipeline transportation, liquefaction, marine transport and regasification—from the net revenues generated from sales in that market.

 

157


Table of Contents

Chart 1: Illustrative Representation of LNG Net Spread ($/MMBtu)

 

LOGO

 

Notes:

Cost of Feedgas assumes illustrative $3.75 Henry Hub. Illustrative assumption based on average Henry Hub forward price per ICE market data. Cost of Liquefaction based on Venture Global Cost of Sales. Illustrative assumption based on historical Cost of Sales at Calcasieu Pass. Shipping Cost reflects ICE data for average Atlantic charter day rate. Assumes 3.6MMBtu per cargo, 28-day roundtrip to Europe. Data and assumptions, except for those labeled as illustrative, are calculated as of November 2024.

Unexpected supply constraints to the natural gas supply market can also create opportunities for LNG producers, particularly those with excess, non-contracted supply to fill market needs. For example, in 2023, approximately 48% of European LNG was purchased in the spot market to fill in the short-term gaps left by the sudden loss of Russian natural gas pipeline flow. Latin America also purchased most of its LNG in the spot market (approximately 66%) in preparation for the winter and subsequent heating needs. LNG short-term contract and spot market sales grew rapidly as supply came online, from approximately 19% of total global LNG trade in 2010 to approximately 35% in 2023, but such sales remain less prevalent than longer-term contracts.

U.S. LNG long-term contract pricing

Most LNG contracts in the U.S. today are priced relative to the price for gas at Henry Hub, which serves as the reference for natural gas future contracts traded on the New York Mercantile Exchange, or NYMEX.

The cost structure of long-term U.S. LNG supply agreements typically has three primary components:

 

  (i)

Feed Gas Costs: With many U.S. LNG producers utilizing tolling models and forgoing ownership of the natural gas itself, feed gas costs reflect the cost of buying the natural gas that will then be liquefied at the LNG facility. Other producers are responsible for purchasing and transporting gas to their facilities. In both approaches in the U.S., feed gas costs are indexed to HH, typically on a 1-for-1 basis. This cost is intended to be a pass-through for LNG producers; the offtaker bears the risk of fluctuations in HH prices

 

158


Table of Contents
  (ii)

Variable Costs: LNG producers typically charge offtakers a premium, usually around 15% of HH pricing, to cover any variable costs at liquefaction projects, including feed gas, power, and transportation costs

 

  (iii)

Fixed Fee: Fixed fees are designed to cover the LNG producer’s fixed maintenance and operating expenses, return on equity, and debt service. A small portion of the fee, between 10% to 20%, usually escalates with inflation. Fixed fees have historically fluctuated between approximately $2.00—$3.00 /MMBtu for long-term contracts, though inflation has pushed these prices higher for new build projects. From September 1, 2022 to September 1, 2024, interest rates rose approximately 240 basis points. As a result of these increasing interest rates, rising labor and materials costs, and continued supply chain challenges in the construction industry, we expect fixed fees to approach $4.52/MMBtu over time. This is the price needed to fully amortize the project financing at required debt service coverage levels and still provide a return on equity to developers and operators

Long-Term Contracts

Long-term LNG SPAs have traditionally been the most common types of LNG supply agreements. Globally in 2023, approximately 61% of LNG was traded under long-term contracts, approximately 4% under short-term contracts, and approximately 35% in the spot market.

Chart 2: Global SPA Duration signed between January 1, 2023, and February 29, 2024

LOGO

 

Source:

IGU World LNG Report, 2024 Edition, dated June 2024.

Long-term SPAs have historically played a central role in the LNG industry for four main reasons:

 

  (i)

Value Chain: The exploration and production of reserves is capital intensive and making such commitments requires a clear path to monetization of the resource. Long-term SPAs granted this clarity to upstream producers and enabled broader investment

 

  (ii)

Financial Security: Long-term “take-or-pay” contracts provide certainty and the financial security necessary for capital-intensive development of LNG projects themselves, including liquefaction plants and associated infrastructure. Project Finance lenders require new build facilities to have executed enough contracts such that the fixed fees payable to the LNG project are sufficient to fully amortize the loans over the duration of the agreements. The creditworthiness of offtakers also plays an important role in LNG project financing. Counterparty risk is largely mitigated as most offtakers are either large investment grade corporations or government-backed entities

 

  (iii)

Reliability of Supply: Buyers, typically utilities and large industrial users, seek long-term contracts to ensure a stable and reliable supply of LNG, crucial for their long-term energy planning. Long-term

 

159


Table of Contents
  contracting grew across the world following the European energy crisis which put a premium on long-term supply certainty. In 2023 alone, interregional trade was dominated by long-term contracts with 68% of global SPAs executed with a duration of more than 10 years

 

  (iv)

Reduce Market Volatility: Long-term agreements help stabilize the market by locking in prices and volumes, reducing exposure to market volatility. These agreements also provide further transparency into future supply as producers must contact potential buyers well in advance of a project’s commercial operations. This transparency provides necessary information for buyers and sellers alike to better forecast their long-term business models

LNG Demand & Supply

LNG Demand

Total global natural gas demand is projected to increase from approximately 153.3 Tcf in 2022 to approximately 197.0 Tcf by 2050 according to the EIA. Additionally, LNG today represents roughly 13% of global natural gas demand and is projected to increase to approximately 19% of global demand by 2050, according to the International Energy Agency’s, or the IEA, World Energy Outlook.

Chart 3: Global LNG Demand through 2050 (mtpa)

 

LOGO

 

Source:

(1)

S&P Global Commodity Insights @2024 by S&P Global Inc., data sourced as of February 2024.

(2)

Illustrative 3.0% Growth Case and Illustrative 5.0% Growth Case reflect illustrative future demand for comparison purposes, based on a hypothetical compound annual growth rate of 3.0% and 5.0%, respectively, applied to 2023 demand and held constant over the projection period. Hypothetical growth rates reflect a range relative to historical compound annual growth rates of 4.5% and 7.3% in Global LNG Trade for the period from 2011 to 2021 and for the period from 2016 to 2021, respectively, according to International Group of Liquefied Natural Gas Importers.

Asian countries such as China and India are rapidly increasing their LNG imports to both meet growing energy needs and to reduce emissions, improve air quality, and comply with stricter environmental regulations. Countries in Europe are similarly looking to diversify their energy sources and reduce dependency on pipeline imports,

 

160


Table of Contents

particularly from Russia. Given their lack of sufficient domestic gas production, these regions will continue to rely heavily on imports from major LNG exporters such as the U.S., Qatar, and Australia over the long-term.

Key Trends Driving Demand

(i) Coal-to-Gas Switching and Decarbonization

Today, more coal is burned on a daily basis than at any point in history. However, decarbonization efforts are driving a shift from coal to natural gas in power consumption due to natural gas’ lower carbon footprint and greater efficiency. As countries and organizations continue to reduce greenhouse gas, or GHG, emissions, natural gas is increasingly favored over coal as it produces approximately 30-60% less carbon dioxide when combusted for power generation. The United States in particular has already benefited from this transition, with total electric power sector CO2 emissions falling by approximately 35% from 2000 to 2022 largely attributable to coal-to-gas switching. Over the same period, the amount of electricity generated annually by coal in the U.S. declined by approximately 1.1 billion KWh. This production was primarily replaced by natural gas-powered electricity, which rose by 1.1 billion KWh over the period. As more countries around the world seek to reduce their GHG emissions, we expect the pace of coal-to-gas switching to accelerate, underpinning sustained demand for natural gas and thus LNG.

Chart 4: U.S. CO2 Emissions Reduction

LOGO

 

Source: EIA’s U.S. Energy Related Carbon Dioxide Emissions, data sourced as of February 2024.

(ii) Renewables Buildout and Grid Reliability

Natural gas is a vital complement to intermittent renewable energy sources due to its ability to provide reliable and on-demand power. Natural gas plants serve as dependable power sources when renewables generation is unavailable due to decreased wind or sunlight. Gas-fired power plants, which accounted for 40% of global natural gas consumption in 2023, can quickly adjust output to match demand, providing flexibility and stability to power grids across the world. This flexibility ensures a stable and continuous energy supply, reducing the risk of power outages and grid instability as the share of renewables in the global fuel mix increases.

(iii) Global Economic and Population Growth

Population growth and the expansion of the world’s middle class further underpin rising global demand for natural gas. By 2050, the global population is projected to rise to approximately 10 billion from approximately 8 billion today, according to IEA’s Global Energy and Climate Model with reference to the

 

161


Table of Contents

medium variant of the United Nations projections for population growth. Concurrently, global disposable net income per capita is projected to increase from $10,136 annually in 2022 to nearly $16,979 annually in 2050, or approximately 1.9% per year, according to the EIA. Additionally, the EIA projects that certain parts of the world including China, India, and other parts of Asia are forecasted to grow at even faster rates of 4.0%, 4.2%, and 2.4%, respectively. With this growth and the continued improvement in global living standards, demand for electricity, heating, and consumer staples are projected to rise rapidly. Despite the global commitment to build out renewables and other low carbon alternatives, this growth and continued improvement will depend on natural gas to affordably stabilize electric grids and support electrification around the world.

Chart 5: Global Population (Bn) and Per Capita Disposable Net Income ($000s per person)

 

LOGO

 

Source:

EIA, International Energy Outlook 2023, sourced as of October 2023.

Chart 6: Median Global Electricity Demand Per Capita (KWh)

LOGO

 

Source:

EIA, International Energy Outlook 2023, dated October 2023.

(iv) AI Driven Data Center Demand Growth

The surge in demand for artificial intelligence, or AI, data centers is a global phenomenon driven by widespread adoption of artificial intelligence across industries, the expansion of cloud computing, and advancements in technology requiring substantial computational power. Due to increased privacy laws and

 

162


Table of Contents

data security concerns, we anticipate that each developed nation will increasingly elect to develop their own data center and AI infrastructure. Existing estimates put global data center capex above $800 billion per year by 2027 with continued acceleration thereafter. This growth is leading to increased energy consumption as data centers house the servers and infrastructure for AI operations and require significant amounts of electricity for both operation and cooling. Global data center driven power demand is projected to increase 74% by 2026 compared to 2022, based on IEA’s “Electricity 2024: Analysis and forecast 2026” report (Base Case). In Europe, data center energy consumption is projected to account for 4.5% of total power demand by 2030, relative to only 2.2% in 2023, according to McKinsey’s 2024 Global Energy Perspective report and calculated based on current rates of adoption. Power generated from natural gas steam turbines offers the most cost effective and carbon efficient option for developers as data center infrastructure continues to proliferate.

Key LNG Markets

Chart 7: Global LNG Demand by Region through 2050 (mtpa)

LOGO

 

Source:

S&P Global Commodity Insights @2024 by S&P Global Inc., data sourced as of February 2024.

Note:

“Other” demand category, which represents S&P’s estimated upside to their LNG demand forecast, and is included as part of S&P’s total LNG demand estimates. Volumes associated with this “Other” demand category are allocated proportionally across regions.

(i) Developed Regions

Natural gas demand growth in developed economies is driven by multiple factors that reflect both the evolving needs of the complex energy landscape and realities of the modern world.

 

163


Table of Contents

Chart 8: Developed Regions Global LNG Demand (mtpa)

LOGO

 

Source:

S&P Global Commodity Insights @2024 by S&P Global Inc., data sourced as of February 2024.

Note:

Middle East includes Bahrain, Israel, Kuwait, Saudi Arabia, and UAE. Other Asia Pacific includes Australia, Hong Kong, Singapore, and Taiwan. North America includes Canada and United States. “Other” demand allocated proportionally across regions.

Chinese demand for natural gas has substantially increased as the country has sought to combat air pollution by replacing the use of low-grade coal with electricity powered by natural gas. This demand, supported by government policies, is intended to offset the approximately 47 GW of coal capacity added in 2023. LNG import growth is projected to increase from 69 mtpa in 2020 to 123 mtpa in 2040, according to data provided by S&P Global Commodity Insights.

In Europe, the Russia-Ukraine War has significantly influenced energy policy and has become a driver of LNG demand as nation-states focus on their energy security. Europe has invested heavily in additional regasification capacity; European LNG regasification projects are projected to increase the continent’s LNG import capacity by 121 mtpa before the end of the decade, according to S&P Global Commodity Insights based on current under-construction and proposed projects. This additional capacity is projected to significantly boost LNG demand, which is forecasted to grow by 29 mtpa over the next decade.

(ii) Developing Regions

Demand for LNG in developing markets is projected to be fueled by rapid demographic and economic growth. As populations grow, they inherently demand more energy for residential, commercial, and industrial uses. The expanding middle class is driving an increased demand for a higher standard of living, including greater access to energy-intensive goods; when incomes double, consumers are found to be approximately 9% more likely to own a refrigerator and approximately 12% more likely to own a computer. Natural gas is projected to be key to meeting the projected increase in demand by offering affordable, clean, and reliable baseload power.

 

164


Table of Contents

Chart 9: Developing Regions Global LNG Demand (mtpa)

LOGO

 

Source:

S&P Global Commodity Insights @2024 by S&P Global Inc., data sourced as of February 2024

Note:

Middle East & North-Africa excludes Bahrain, Israel, Kuwait, Saudi Arabia, and UAE. Asia Pacific excludes Australia, China, Hong Kong, Japan, Singapore, South Korea, and Taiwan. North America excludes Canada and United States. “Other” demand allocated proportionally across regions.

Developing regions are projected to experience robust LNG demand growth with Southeast and South Asia a part of the fastest-growing LNG markets. Developing regions’ increase in demand is spurred by a 31% projected increase in population (equivalent to 1.6 billion people) by 2050, as categorized by the United Nations and excluding China, according to population models developed by the United Nations Population Fund. This growth is further compounded by increasing urbanization and levels of disposable income increasing at a rate of as fast as 4% per year in certain countries. With domestic gas production in terminal decline for many nations in the region, LNG imports are projected to materially ramp up through and beyond the 2040s to support these macroeconomic trends.

LNG demand in other developing regions outside of Asia is also projected to steadily grow. In both Africa and South America, natural gas demand growth is projected to outpace domestic supply growth, increasing reliance on imported LNG. African demand is projected to be driven by strong economic expansion, continued industrialization and rapidly rising urban population, accompanied by an accelerated increase in electricity needs. With these macroeconomic changes, African LNG imports are projected to triple by 2030. Meanwhile in South America, key demand growth drivers include fuel switching, industrial development, baseload power to backup intermittent renewables, and road transportation. The region is consequently projected to see LNG imports rise from 6 mtpa in 2023 to 15 mtpa in 2040, according to data provided by S&P Global Commodity Insights.

 

165


Table of Contents

LNG Supply

Current global LNG production capacity stands at approximately 459 mtpa, with the majority concentrated in regions such as the U.S. (18% share of total capacity), Australia (19%) and Qatar (17 %). In 2023, these three countries produced 61% of the world’s LNG supply.

Chart 10: Global LNG Supply Forecast (mtpa)

LOGO

 

Source:

S&P Global Commodity Insights @2024 by S&P Global Inc., data sourced as of February 2024

Note:

Total supply includes existing supply and supply from projects under construction. Excludes proposed projects as categorized by S&P Global Commodity Insights.

According to data provided by S&P Global Commodity Insights, global LNG supply from projects in operation and under construction is projected to reach 563 mtpa by 2035. This represents a 39% increase from 2023 levels. Approximately 181 mtpa of LNG capacity is currently under construction, with approximately 30% coming from expansion projects. Projects under construction are projected to represent over 26% of expected supply by 2030. The projected new supply will primarily come from the U.S., Qatar, and floating LNG projects in Africa. The U.S. is at the forefront with five major projects under construction comprising approximately 42% (approximately 70 mtpa) of total projected supply addition by 2030.

Many projects aspire to reach FID in the coming years, but not all will succeed. Developing LNG projects is a complex and challenging process that requires careful planning, significant resources, and expertise. Additionally, LNG projects often face delays due to external factors such as labor costs and supply chain disruptions, financing challenges and regulatory hurdles. For example, an all-time high of more than 70 mtpa of capacity reached FID in 2019 but many had their production start dates delayed. Qatar saw the timeline of its 48 mtpa North Field Expansion project delayed due to supply disruptions. Golden Pass, an 18 mtpa project in the U.S. by QatarEnergy and ExxonMobil, is behind schedule due to construction issues. Mozambique LNG, a approximately 13 mtpa project led by TotalEnergies, has been halted since 2021 and is still under force majeure due to security concerns arising from violent insurgent attacks in the region. If this level of capacity approved in 2019 were not impeded, the market would see an additional 20-36 mtpa of supply per year from 2025 to 2027. These challenges are not new or novel in the LNG industry. For instance, LNG Canada, a Shell sponsored project, which was first announced in 2012, did not take FID until 2018, and has been delayed multiple years so far with first LNG currently targeted for mid-2025. Based on certain S&P Global Commodity Insights data, should under-construction projects be further delayed by an additional 12 months, that delay would lower anticipated supply by as much as 40 mtpa in each of 2025 and 2026.

 

166


Table of Contents

Declining production curves from historic export centers of oil and gas also weigh on future projections of LNG supply. In Southeast and South Asia, total production from existing facilities in Indonesia, Malaysia, and Brunei is projected to decline from 48 mtpa in 2023 to 46 mtpa in 2030. Production from legacy assets in Africa are projected to remain relatively stable at approximately 45 mtpa. Further, Trinidad and Tobago, which boasts a 16 mtpa facility, has seen reduced flows from its gas fields leading to the idling of liquefaction capacity. These declines in supply further underpin the need for LNG project development in the near term, particularly in regions like the U.S. that house multiple, discontinuous natural gas basins. LNG projects fed by a single basin are necessarily constrained by the supply of a single location. Conversely, projects in the U.S. enjoy diversified sources of supply accessible by robust, layered transportation infrastructure.

United States

The U.S. exported over 86 million tons of LNG in 2023, claiming the lead spot among global LNG exporters. There are seven operating LNG facilities in the continental U.S. with a combined capacity of 92 mtpa of LNG (Calcasieu Pass LNG, Cameron LNG, Corpus Christi LNG, Cove Point LNG, Elba Island LNG, Freeport LNG and Sabine Pass LNG). These facilities represent one fifth of the world’s total LNG production capacity. Current U.S. LNG projects under construction are projected to add as much as 85 mtpa of export capacity by 2030, barring delays.

LNG supply in the U.S. is bolstered by strong, enduring supply and technology trends, driving its swift ascent to the top as the world’s leading LNG exporter. To start, the U.S. has the largest share of natural gas production among all regions globally, accounting for 26% of total natural gas production in 2023. U.S. gas production continues to steadily rise, recently growing 4.3% from 2022-2023. This growth is primarily driven by the increase in production from prolific gas regions in the Permian Basin and Haynesville Shale. U.S. proved natural gas reserves are estimated at 691 Tcf, reflecting the nation’s significant resource potential. Advancements in extraction technologies such as hydraulic fracturing and horizontal drilling continue to enhance production efficiency and reduce costs. A robust, well-established network of transportation pipelines facilitates distribution of natural gas from the wellhead to end demand.

Chart 11: U.S. LNG Supply Forecast (mtpa)

 

LOGO

 

Source:

S&P Global Commodity Insights @2024 by S&P Global Inc., data sourced as of July 2024

 

167


Table of Contents

Middle East

The Middle East is a critical player in the global LNG market, with Qatar, Oman, and the United Arab Emirates, or UAE, leading the region’s export capabilities. Qatar is a dominant supplier with a current production capacity of 81 mtpa. This capacity is primarily sourced from the vast North Field, the largest non-associated natural gas field in the world. The total estimated recoverable reserves of the North Field are approximately 900 Tcf of natural gas. Oman and the UAE’s export capabilities are more modest in comparison. Oman holds 12 mtpa of LNG capacity across its facilities in Qalhat and Sur. UAE operates a 6 mtpa facility on Das Island.

The Middle East’s LNG production is sustained by its vast and easily accessible natural gas reserves. The region’s growing infrastructure, including pipelines and export facilities, strengthens production and distribution. Access to capital allows significant investment in exploration and technological advancement. Further, the Middle East’s proximity to major energy markets in Europe and Asia reduces transportation costs.

Qatar, Oman, and the UAE are actively planning to develop additional LNG projects to further expand their export capabilities. Qatar plans to increase liquefaction capacity to 112 mtpa by 2030 through its North Field expansion projects. However, this proposed expansion is not without risk. For example, delays in the bidding process have already extended its timeline. Additionally, the UAE’s state-run Adnoc approved the approximately 10 mtpa Ruwais project in June 2024, which is projected to begin production in 2028. TotalEnergies is also moving ahead with the 1 mtpa Marsa LNG bunkering project in Oman, slated for 2028 commencement. This project will primarily supply marine fuel for the Gulf region.

Chart 12: Middle East LNG Supply Forecast (mtpa)

 

LOGO

 

Source:

S&P Global Commodity Insights @2024 by S&P Global Inc., data sourced as of July 2024

Middle Eastern gas production entails several unique risks. LNG producing countries in the region are dependent on large, single-source fields, which make supply vulnerable to disruptions. The concentration of liquefaction sites in a few strategic locations also poses logistical and security challenges. Heightened geopolitical risks including regional conflicts and political instability may threaten production and export continuity. For example, ongoing regional wars are disrupting key shipping channels in the Strait of Hormuz and the Suez Canal. Such disruptions have plagued regional supply chains for decades and are not limited to the present conflicts.

 

168


Table of Contents

Australia

Australia is one of the world’s largest LNG producers. In 2023, Australia exported 82 million tons of LNG. Australia’s rise as a world leader in LNG production has been driven by several key factors. The country has sizable natural gas reserves in Western Australia and Queensland. Moreover, its strategic geographic location close to major Asian markets allows for efficient export routes and low shipping costs. Lastly, Australia’s regulatory environment helped attract investment to the LNG sector. Australia’s LNG supply is projected to remain stable throughout the decade, averaging around 80 mtpa, although escalating construction costs and a tightening domestic gas market could constrain exports in the future. For example, in 2024, the Northern Territory government had to execute emergency gas deals that limited LNG exports due to declining production at the Blacktip field. Australia’s East Coast is forecast to experience gas shortfalls starting in 2028.

Chart 13: Australia LNG Supply Forecast (mtpa)

 

LOGO

 

Source:

S&P Global Commodity Insights @2024 by S&P Global Inc., data sourced as of July 2024

Note:

Total supply includes existing supply and supply from projects under construction. Excludes proposed projects as categorized by S&P Global Commodity Insights.

Russia

Russia is a significant player in the global LNG market. In 2023, Russia exported 32 million tons of LNG. Russia’s LNG production is supported by its abundant natural gas reserves, particularly in the Yamal Peninsula and Artic regions. Further, its production capacity is strategically enhanced by its proximity to European and Asian markets. The Northern Sea Route in particular, facilitates shorter shipping times to Asia. Key LNG facilities include the Sakhalin-2 project, Yamal LNG, Petrovaya LNG and Vystosk LNG. In 2023, Russia continued to supply almost16 mtpa of natural gas to Europe.

Russia’s plan to triple LNG output by 2030 has been derailed by the extensive rounds of sanctions following its invasion of Ukraine in 2022. These sanctions are not only stalling projects under-construction but also posing a risk to current operational facilities. Sanctions imposed on Russia by Western nations in response to the invasion of Ukraine in 2022 have had significant repercussions on the country’s LNG production and export capabilities, making future supply of Russian gas uncertain.

 

169


Table of Contents

Chart 14: Russia LNG Supply Forecast (mtpa)

 

LOGO

 

Source:

S&P Global Commodity Insights @2024 by S&P Global Inc., data sourced as of July 2024

Supply and Demand Imbalance

Given the factors discussed above, an undersupply of LNG by 2040 of 110 mtpa is being projected. This shortfall is projected to widen to 211 mtpa by 2050.

Chart 15: Combined LNG Supply and Demand Forecast (mtpa)

 

LOGO

 

Source:

S&P Global Commodity Insights @2024 by S&P Global Inc., data sourced as of February 2024

Note:

Total supply includes existing supply and supply from projects under construction. Excludes proposed projects as categorized by S&P Global Commodity Insights.

Further, it is possible that this shortfall is understated. Historic projections of demand have failed to accurately predict growth in demand, often understating it by an appreciable margin. For example, the

 

170


Table of Contents

International Energy Agency, an intergovernmental entity, publishes an annual World Energy Outlook that is utilized by governments to inform policy decisions. The report often includes projections of LNG demand globally. Their projections for 2010, 2015, and 2020 understated realized demand by 41% on average across reports dating back twenty years.

Likewise, projections of supply in the LNG market also can be overstated. LNG projects face a litany of challenges to reaching production including siting, regulatory, contracting, financing, construction, and operational headwinds. As can be seen in the chart below, even large multi-national corporations and nation states have struggled to reach first production of LNG in line with initial expectations, often seeing delays of multiple years compared to their initially announced timelines.

Chart 16: LNG Project Timelines

 

LOGO

 

Source:

Public company filings and announcements, data sourced as of November 2024

Taken together, these trends in conservative estimates of demand and overly optimistic projections of supply present the possibility of an even wider supply and demand gap than is currently anticipated by market analysts and participants. Such an imbalance may raise LNG prices from recent levels and provide opportunities for LNG project developers to meet the coming demand.

Rise of U.S. Liquefaction

The United States has emerged as one of the global powerhouses in LNG production by leveraging its vast natural gas reserves, cutting-edge extraction technologies, extensive pipeline infrastructure, and broadly supportive political and regulatory environment. Additionally, its strategic location and the development of LNG terminals along the Gulf Coast provides access to key global markets. While historically the U.S. has been an importer of natural gas, recent technology advancements and investments have transformed the country into a net exporter with the proceeds from exports broadly distributed throughout the U.S. economy. LNG exports have bolstered the U.S. trade balance, particularly with China, and generated substantial local, state, and federal tax revenue. Each LNG project requires thousands of construction jobs and hundreds of permanent operations jobs, with cascading effects through the financial and legal services and domestic manufacturing sectors.

The surge in U.S. LNG production not only generates substantial economic benefits—such as job creation, trade deficit reduction, and increased local, state, and federal revenues—but also plays a critical role in global energy security. U.S. LNG offers an alternative to more carbon intensive energy sources, while also promoting adherence to stringent environmental and social standards, thereby contributing to the global effort to reduce emissions.

 

171


Table of Contents

Abundant Natural Gas Resources

Chart 17: U.S. Natural Gas Basins and Pipeline Infrastructure

 

LOGO

 

Source:

U.S. Energy Information Administration, “Natural gas explained: Natural gas pipeline” and U.S. Energy Information Administration, “Natural gas explained: Where our gas comes from”, prepared as of November 2024

The U.S.’s substantial natural gas reserves position the country as one of the world’s leading producers and exporters of natural gas. The U.S.’s proved natural gas reserves are estimated at approximately 691 Tcf. These reserves are primarily concentrated in key areas including the Marcellus and Utica Shales (both in Appalachia), Permian Basin (includes Delaware and Midland), Haynesville Shale, and Eagle Ford Shale. These ample reserves offer a robust foundation for meeting domestic energy needs and expanding exports to global LNG markets. Furthermore, production of natural gas in the U.S. has been increasing since 2006 and the rate of increase has accelerated since 2017. In 2023, U.S. natural gas production grew by 4%, or 4.0 billion cubic feet per day (Bcf/d), to 104.0 Bcf/d. In the same year, global gas production only increased by 0.7%, driven by the production expansion in the U.S. and European production decline. Natural gas production in the U.S. is projected to keep growing, reaching 115.3 Bcf/d by 2050.

 

172


Table of Contents

Chart 18: U.S. Natural Gas Production (Bcf/d)

 

LOGO

 

Source:

U.S. Energy Information Administration, “Short Term Energy Outlook”, August 2024

The Appalachian, Permian, and Haynesville Basins are the richest natural gas basins in the U.S. Each holds various formations with large natural gas reserves.

 

  (i)

The prominent shales in the Appalachian Basin are the Marcellus and Utica shales. The Marcellus Shale, with an estimated 500 Tcf of recoverable gas, is one of the largest natural gas reserves globally. Additionally, the Utica Shale reserves are estimated at around 117 Tcf. In 2023, more natural gas was produced in the Appalachia region than in any other U.S. region. Total production reached 37.7 Bcf/d, which represents 29% of gross natural gas production.

 

  (ii)

The Permian Basin is located in western Texas and southeastern New Mexico and is home to multiple resource formations, including the Wolfcamp, Spraberry, and Bone Spring, and holds almost 300 Tcf of natural gas. The Permian region produces the second-most natural gas in the U.S., accounting for 19% of domestic production. Additionally, since early 2023, the Permian region has had more active rigs than all other natural gas deposits in the Lower 48 states combined. Natural gas production growth in the Permian region is largely driven by the increase in associated gas generated during oil extraction. Oil is historically the key focus of the region and consolidation amongst producers has led to an increase in both production and the need for pipeline offtake of associated gas. In 2023, gross natural gas production in the Permian region rose by 2.6 Bcf/d to an average 23.3 Bcf/d. This increase has played a role in expanding the basis differential between Permian volumes and those sold at Henry Hub. As a result, there has been increased development of long-haul pipelines seeking to alleviate the oversupply.

 

  (iii)

The Haynesville Shale located in northwest Louisiana and eastern Texas has an estimated recoverable resource base of approximately 250 Tcf of natural gas. In 2023, the Haynesville region accounted for 13%, or 16.8 Bcf/d, of gross natural gas withdrawals, a 1.4 Bcf/d increase from 2022. In 2022, natural gas production in the Haynesville region had grown by 2.1 Bcf/d. Natural gas production growth in the region is fueled by a favorable regulatory environment and its proximity to the Gulf Coast LNG export facilities such as ours.

The U.S. was a historical net importer of natural gas importing on average approximately 26 mtpa from 2010 to 2016. Advancements in efficient extraction technologies, particularly hydraulic fracturing, have

 

173


Table of Contents

significantly lowered natural gas prices and led to the U.S. becoming a net exporter of natural gas in 2017 for the first time in approximately 60 years. In 2023, the U.S. became the world’s largest exporter of LNG, surpassing Qatar and Australia with 89 mtpa of exports.

Chart 19: U.S. Natural Gas Production vs. Consumption

 

LOGO

 

Source:

U.S. Energy Information Administration, Monthly Energy Review, Table 1.2, preliminary data for 2023, sourced as of April 2024

Extensive Pipeline Infrastructure

The U.S. distinguishes itself with its advanced natural gas infrastructure, featuring an extensive pipeline network and highly efficient storage facilities. This robust system enhances energy reliability and ensures low transportation and distribution costs. The existing pipeline infrastructure enables the transport and storage of natural gas from supply locations to coastal areas in the U.S., where it is liquefied and shipped. As a result, while other nations struggle to transport natural gas for export, U.S. LNG producers can offer competitively priced LNG globally.

U.S. natural gas domestic infrastructure includes approximately three million miles of pipelines divided into intrastate and interstate systems. This vast network supports the transportation of around 80 Bcf/d of natural gas. This expansive infrastructure enables Venture Global’s facilities to source natural gas from multiple regions across the nation, ensuring we are not dependent on any single natural gas basin or pipeline for natural gas feedstock.

The U.S. is currently investing $11.5 billion to build well over 1,000 miles of new natural gas pipeline. This pipeline infrastructure expansion is largely focused on expanding existing transmission capacity or increasing export capacity from the Permian Basin and Haynesville Shale. The ambitious and ongoing buildout of pipeline infrastructure is aimed at serving the Gulf Coast LNG export terminals, which is where our liquefaction sites are located. Key projects include the 2.5 Bcf/d Matterhorn Express 580-mile pipeline and the 2.0 Bcf/d 563-mile Apex pipeline, both designed to improve transport from production hubs to export facilities in the Gulf Coast. This increased pipeline capacity enables natural gas producers to expand production, as natural gas can be efficiently transported from extraction sites to end markets without logistical constraints.

 

174


Table of Contents

BUSINESS

Overview

Our Company

Venture Global has fundamentally reshaped the development and construction of liquefied natural gas production, establishing us as a rapidly growing company delivering critical LNG to the world. Our innovative and disruptive approach, which is both scalable and repeatable, allows us to bring LNG to a global market years faster and at a lower cost. We believe supplying this clean, affordable fuel promotes global energy security and is essential to meeting growing global demand.

Natural gas is one of the most important resources worldwide and is required to generate reliable electricity that underpins economic development and drives industry. Once natural gas is supercooled to -260°F, it converts to liquid form and reduces to 1/600th of its original volume, enabling large quantities of natural gas to be loaded and shipped by LNG tankers. The resulting LNG can be transported to international markets that lack domestic supply, displacing more carbon intensive sources of energy such as coal, diesel, and heavy fuel oil, and serving as an integral part of a cleaner energy future. We believe our business model has demonstrated that in a competitive commodity market, lower cost and overall faster delivery wins market share. Our approach capitalizes on both of these advantages, supporting significant additional growth opportunities.

Our Projects

We are commissioning, constructing, and developing five natural gas liquefaction and export projects near the Gulf of Mexico in Louisiana, utilizing our unique “design one, build many” approach. Each project is designed or is being developed to include an LNG facility and associated pipeline systems that interconnect with several interstate and intrastate pipelines to enable the delivery of natural gas into the LNG facility. As illustrated by the chart below, our five current projects are being designed to deliver a total expected peak production capacity of 143.8 mtpa, which consists of an aggregate of 104.4 mtpa expected nameplate capacity and an aggregate of 39.4 mtpa of expected excess capacity. These amounts do not account for any potential bolt-on expansion liquefaction capacity. The expected nameplate capacity of our facilities measures the minimum operating performance thresholds guaranteed by the equipment providers, and the expected excess capacity represents the additional LNG that we aim to produce above such guaranteed amounts. Although COD has not yet occurred under the post-COD SPAs for any of our projects, we have been generating proceeds from the sale of commissioning cargos at the Calcasieu Project since the first quarter of 2022, and expect to do so at each of our other projects during commissioning prior to achieving COD for the relevant project or phase of a project.

 

LOGO

 

(1)

Targets based on, among other things, anticipated timeframes for the receipt of certain regulatory approvals as described in “—Governmental Regulation.”

(2)

Anticipated based on capacity, scale, location and infrastructure. Subject to regulatory review and approval, among other things, and may change based on design considerations, engagement with contractors, and other factors.

 

175


Table of Contents

Our Project Development and Construction Approach

The traditional approach to developing large-scale LNG facilities involves very large, highly customized, stick-built projects consisting of two to three liquefaction trains that are constructed almost entirely onsite by vast workforces. In addition, many of these large stick-built projects are built in remote locations far from concentrated sources of experienced construction workforces, adding to their execution risks. Using this traditional approach, construction can last well over five years and in some cases has lasted nearly a decade.

In contrast, our project development and construction approach utilizes proven liquefaction system technology and equipment in a unique mid-scale, factory-fabricated configuration that we developed. Instead of two or three large, complex liquefaction trains, the Calcasieu Project and the Plaquemines Project utilize 18 and 36 mid-scale factory-fabricated liquefaction trains, respectively. We expect to use the same approach and technology at the CP2 Project, the CP3 Project and the Delta Project. Our modules are built and assembled off-site at manufacturing and fabrication facilities in Italy and then shipped to our project sites fully-assembled and packaged for installation, allowing onsite work to progress in parallel. We believe our innovative configuration, long-term equipment contracting strategy and hands-on project management approach significantly reduces construction and installation costs, as well as construction time and schedule risk, thereby allowing us to be more cost-competitive in the LNG market while also producing substantial amounts of commissioning cargos and related cash proceeds. For example, our initial two projects, the Calcasieu Project and the Plaquemines Project, in each case, began producing LNG approximately two and a half years after its final investment decision, while significant construction work remained ongoing. The chart below illustrates the length of time the Calcasieu Project and the Plaquemines Project took to achieve first production of LNG after achieving FID relative to other projects that also achieved FID substantially contemporaneously and are not producing LNG as of the date of this prospectus.

LOGO

While traditional LNG projects often rely on bespoke designs and configurations, our approach, leveraging factory-fabricated equipment manufactured with our “design one, build many” method, allows us to apply the lessons we learn at each project to our subsequent projects, with the goal of continuously improving our execution, accelerating construction timelines, reducing costs, and expanding production. We believe we will continue to benefit from this virtuous cycle as we grow.

Gas Supply and Transportation

We have entered into a portfolio of natural gas supply agreements with domestic natural gas suppliers to furnish feed gas to the Calcasieu Project and the Plaquemines Project for liquefaction and power generation. We have also entered into multiple transport capacity agreements with interstate pipeline companies to provide natural gas transportation to the Calcasieu Project and the Plaquemines Project via short-run lateral pipelines. The CP2 Project has already entered into agreements with third parties for substantial firm transportation capacity and is developing its own pipeline. The CP3 Project and the Delta Project will require their own proposed pipeline routes and we aim to enter into transportation agreements with interstate pipeline companies in connection with the CP2 Project, the CP3 Project and the Delta Project as development progresses.

 

176


Table of Contents

LNG Sales – Commissioning

By design, conventional, stick-built projects generally only engage in several months of commissioning production, thereby limiting the number of cargos produced before full commercial operations occur. Due to our unique modular development approach and configuration consisting of many mid-scale liquefaction trains, which are delivered and installed sequentially, it is necessary to commission and test our LNG facilities sequentially over a longer period of time than traditional LNG facilities with substantially fewer, larger-scale liquefaction trains. The commissioning of the liquefaction trains at our facilities begins while portions of our facilities remain under construction.

This important reliability and technical requirement results in earlier production of LNG than with traditional LNG facilities. We believe this earlier production of LNG positions us to produce a substantial number of commissioning cargos for each of our LNG projects, generating proceeds that may be used to support any remaining construction work or fund subsequent projects and future growth. As an example of this, on March 1, 2022, we announced the successful loading and departure of our first cargo of LNG from the Calcasieu Project, just over two and a half years from our final investment decision for the project. By September 30, 2024, we had loaded and sold 342 LNG commissioning cargos and received approximately $19.6 billion in gross proceeds from such commissioning cargos.

LNG Sales – Post-COD SPAs

The project companies for the Calcasieu Project, the Plaquemines Project and the CP2 Project have signed LNG sales and purchase agreements, or SPAs, to sell LNG based on a pre-determined pricing formula that commences after we achieve the commercial operations date, or COD, of the relevant project or phase thereof. Under each such post-COD SPA, COD does not occur unless the applicable project company has notified such customer that (i) all of the project’s facilities have been completed and commissioned, including any ramp up period, and (ii) the project is capable of delivering LNG in sufficient quantities and necessary quality to perform all of its obligations under such post-COD SPA.

As of September 30, 2024, we have executed 39.25 mtpa of such post-COD SPAs with a well recognized set of third party customers that we believe constitute one of the strongest portfolios of institutional LNG buyer credits in the world. Approximately 95% of our contracted post-COD SPAs – or 37.45 mtpa of such 39.25 mtpa – are 20-year fixed price agreements, providing a long-term stream of contracted cash flow. We have also executed 1.8 mtpa of post-COD SPAs on a short- and medium-term basis and we plan to continue to optimize our portfolio balancing profit, duration, and risk.

Excess Capacity

LNG projects are typically able to achieve production beyond their guaranteed nameplate capacities. For many traditional large international stick-built projects, generating additional production capacity generally requires substantial incremental equipment and construction, with associated injections of capital. By comparison, we believe our projects will have the potential to produce materially beyond their nameplate capacities, with modest incremental capital investment because of our modular design as well as redundancy features inherent in our project design.

We aim to construct and maintain LNG facilities that are capable, in most cases, of producing excess capacity of at least 30% of their guaranteed nameplate capacity, which provides the potential for additional cash proceeds from our projects. Any such excess capacity will generally be available to us to sell on a short-, medium-, or long-term basis, providing flexibility to optimize pricing. With respect to the Calcasieu Project, our inaugural project, we expect to produce excess capacity of slightly less than 30% of its nameplate capacity and we have received FERC approval for a maximum production capacity of 12.4 mtpa. We have contracted to sell a portion of the Calcasieu Project excess capacity to a third-party pursuant to a long-term SPA.

 

177


Table of Contents

Optimization and Bolt-on Expansion Opportunities

Our projects also offer potential optimization, increased capacity and expansion opportunities. In particular, our projects are sited and designed with the intention of allowing for bolt-on expansions, incorporating laydown area, redundancies across the facility infrastructure and our mid-scale factory-fabricated liquefaction trains. Subject to receiving the requisite regulatory approvals, we intend to pursue the development of these expansion opportunities beyond our current combined expected peak production capacity of 143.8 mtpa. Any incremental equipment would benefit from pre-existing plant facilities and related infrastructure (such as marine offloading facilities, LNG storage tanks and perimeter walls). We aim to place up to an aggregate of approximately 35.3 mtpa of additional bolt-on expansion liquefaction capacity of incremental modular mid-scale liquefaction trains at most of our current projects.

Potential Additional LNG Projects and Further Integration

In addition to our current projects, we regularly explore opportunities, both domestic and international, to develop or acquire other potential natural gas liquefaction and export projects, as well as other complementary, synergistic or ancillary projects, in the ordinary course of our business. As described below, we have already engaged in substantial activities to establish complementary pipeline projects, LNG tanker and regasification business lines that could be leveraged for other potential natural gas liquefaction and export projects in the future. Our experienced project execution team, who have deep industry expertise in the LNG, shipping, midstream and construction industries, possess the institutional agility and capital to rapidly evaluate and act upon opportunities as they arise and we believe differentiate us from our competitors.

Pipeline Projects

We are in the advanced stages of development to establish complementary gas transportation for our development projects. As an example, we have partnered with WhiteWater Midstream, LLC, a Texas-based pipeline developer and operator, and entered into a limited liability company agreement with one of their affiliates pursuant to which we hold 50% of the equity interests in Blackfin Pipeline Holdings, LLC, through which we will jointly develop, permit, site and indirectly own the approximately 190 mile Blackfin pipeline project, a long-haul 48-inch intrastate pipeline designed to facilitate the transportation of Permian sourced gas from the Matterhorn Express pipeline to certain interconnecting pipelines, including the CP Express Pipeline. Under the limited liability company agreement, we have agreed to fund certain construction and development costs and seek to arrange a financing to support the Blackfin pipeline project. We believe that gas transportation projects such as this will help further integrate major sources of gas supply with the projects we may develop in the future.

Shipping

In order to vertically integrate our business and expand our customer base to premium markets that have no or limited LNG transportation resources, we have contracted to acquire nine LNG tankers being constructed by two of the premier shipbuilders in South Korea, with two already delivered. The remaining LNG tankers are under construction and are scheduled to be delivered on a rolling basis through 2026. All nine of such newbuild LNG tankers will be primarily fueled by LNG and are designed with best-in-class environmental and efficiency technology. LNG tankers which run on LNG, such as ours, can reduce CO2 emissions by 20-30% compared to tankers that operate with heavy fuel oil. We plan to have our tankers equipped with engines that are designed to significantly reduce methane slip by approximately 66% or more, versus the standard engines used on legacy LNG carriers. Also, we believe our LNG tankers are far more energy efficient than what is typical, due to a hydrodynamic hull design, which is expected to reduce propulsion power by approximately 10%, and the implementation of an air lubrication system that is intended to reduce hull friction and propulsion power requirements by approximately 3%. We have also executed two short-term charters for additional LNG tankers, which were delivered in August and September 2024, bringing our total shipping portfolio to a total of eleven

 

178


Table of Contents

tankers. We believe these LNG tankers will support our ability to optimize LNG marketing and sales and differentiate us from many other LNG exporters in North America.

Regasification

We are also pursuing opportunities to secure LNG regasification capacity in key import markets. As part of this initiative, we have acquired firm regasification facility capacity at the largest LNG regasification terminal in Europe, Grain LNG, in the United Kingdom, which we expect will allow us to import 42 LNG cargos per year from approximately 2029 until 2045 (apart from a limited period). Additionally, we have secured approximately 1 mtpa of LNG regasification capacity at the new Alexandroupolis LNG receiving terminal in Greece for five years, beginning in 2025. Our capacity will account for approximately 25% of the total terminal capacity at Alexandroupolis, or approximately 12 cargos annually. We believe these contracted capacities will allow us to supply LNG and regasified natural gas directly into the European market to current and additional downstream customers. As in the case of our shipping business, many LNG developers have elected to forego integrating regasification into their broader business. Relatedly, many LNG customers lack direct access to regasification capacity. We believe our regasification access will allow us to offer spot and term customers a differentiated service, ultimately positioning us to win market share.

Our Strengths

Our business has a number of competitive strengths, including the following:

 

   

Industry leading growth in the critical global LNG market. We believe that we are the fastest growing developer of LNG facilities in the competitive global supply market. Since the second half of 2019, Venture Global and its affiliates have reached final investment decision for three large-scale, greenfield liquefaction facilities (consisting of the Calcasieu Project and Phase 1 and Phase 2 of the Plaquemines Project) being developed in the United States. We believe that, during this same period, no other developer achieved such a milestone for more than a single large-scale infrastructure project in the world. We expect to increase our LNG production capacity further as we continue our work to optimize our existing projects and develop the CP2 Project, the CP3 Project, the Delta Project, bolt-on and other expansion opportunities, and other investments.

 

   

Accelerated construction schedule and low-cost LNG model. We believe that our disruptive and innovative configuration and owner-led engineering, procurement and construction approach reduces our construction and installation costs, construction time and construction schedule risk, thereby reducing overall project costs and enabling us to produce and sell LNG on an accelerated basis to our customers, as a result of the following:

 

   

Focus on minimizing the time to first LNG. At our first project, the Calcasieu Project, we were able to produce and load LNG for sale approximately two and a half years after the final investment decision, while simultaneously commissioning and constructing the facility, which is substantially faster than the industry average of five years. Although our second project is designed to produce twice the amount of LNG as our first project, we achieved first production of LNG and commenced loading LNG for sale on a similar timeframe. We also aim to improve the pace of bringing incremental trains online at each of our projects.

 

   

Construction and installation execution. Manufacturing our mid-scale, factory-fabricated liquefaction trains, power equipment, gas pre-treatment modules and pipe racks off-site at fabrication facilities allows site works to progress in parallel. Our liquefaction trains and pre-treatment modules are tested and delivered ready to install, reducing on-site labor and potential weather risk while shortening construction timelines and improving overall project safety. Fabrication and installation efficiencies are achieved as the various trains, equipment, and modules are installed on-site and commence production incrementally. Using our “design one, build many” approach, lessons learned from construction, installation, and commissioning work at

 

179


Table of Contents
 

the Calcasieu Project are being carried over to the Plaquemines Project and our subsequent projects. Further, using our owner-led development model, we actively manage the construction activity and the schedule for certain scopes of work undertaken by our key contractors. In addition, we have built an internal EPCM capability, securing a team of experienced leaders and professionals from the EPC industry, primarily with prior relevant experience constructing the Calcasieu Project and the Plaquemines Project facilities.

 

   

Incremental commissioning and LNG production proceeds provide substantial cash proceeds. As each project’s liquefaction trains are brought online, sequentially, and early in construction, the project incrementally produces greater quantities of LNG that may be sold into the market. Once all individual components have been commissioned, production continues while we complete full commissioning of the integrated facility and conduct any carryover or rectification work. During such process, we complete performance testing of the entire fully-integrated facility and validate reliable operational performance. We expect that each project’s construction plan and sequencing will be designed to allow LNG to be produced, stored and loaded onto ships for export, and sold as commissioning cargos, generating cash proceeds.

 

   

Substantial ownership and direct oversight of a diversified LNG project portfolio. Venture Global seeks to own all or substantially all of the equity ownership in its current five LNG projects and any future projects. As of the date of this prospectus, we own 100% of the common equity interests in the Calcasieu Project, the Plaquemines Project, the CP2 Project, the CP3 Project and the Delta Project. Upon COD for the Calcasieu Project, we expect our ownership of the common equity interests in the Calcasieu Project to be reduced to approximately 77% (assuming that we service all future distributions on the Holdings Preferred Units until the commencement of COD in cash), after adjusting for the automatic conversion of the convertible preferred units in Calcasieu Holdings held by an outside equity investor. We believe that our significant ownership stake in our projects provides us with full managerial control, facilitating nimble decision-making and speed of execution.

 

   

Stable, long-term cash flows and valuable commissioning cargos and excess cargos.

 

   

Long-term take-or-pay contracts with highly creditworthy offtakers. We anticipate that our business model will provide us with stable cash flows as a result of our long-term take-or-pay contracts to sell LNG. As of September 30, 2024, we have executed 39.25 mtpa of post-COD SPAs with a set of third party customers that we believe constitute one of the strongest portfolios of institutional LNG buyer credits in the world. The entire expected nameplate capacity for the Calcasieu Project (10 mtpa) and the Plaquemines Project (20 mtpa), and 9.25 mtpa of the CP2 Project, have been contracted under such SPAs. Our third-party post-COD SPAs as of September 30, 2024 represent expected total contracted revenue of approximately $107 billion over the life of such SPAs. Our total contracted revenue is illustrative only and is based on a number of important assumptions. See “Risk Factors—Risks Relating to Our Business—Total contracted revenue is based on certain assumptions and is presented for illustrative purposes only and actual sales under our SPAs may differ materially from such illustrative operating results.” The weighted average life of all of our post-COD SPAs is approximately 19 years, providing a long-term runway of reliable cash flows.

 

   

Valuable and substantial commissioning cargo and excess cargo cash proceeds. Prior to achieving COD under our post-COD SPAs, our post-COD SPAs permit us to generate and sell commissioning cargos to customers at market-based prices, which we believe can unlock significant value to Venture Global. This approach has the potential dual benefit of helping to mitigate risks related to commencement of commercial operations and generating significant cash flow that can be reinvested into the business. For example, since the commencement of commissioning work, the Calcasieu Project has loaded and sold 342 commissioning cargos as of September 30, 2024 and received approximately $19.6 billion in gross proceeds from such

 

commissioning cargos. In addition, after COD occurs under our post-COD SPAs, to the extent not

 

180


Table of Contents
 

already contracted with third parties, we can sell any LNG generated by our projects above the nameplate capacity to customers at market-based prices, providing potential revenue upside over the long term. Proceeds generated from the sale of commissioning cargos and excess cargos provide us with additional cash proceeds and contingency to support project completion and can help fund the development of our other projects.

 

   

Strategic project locations with capacity for substantial expansions. We are developing our current portfolio of projects on strategic locations in Louisiana, which we believe have significant advantages relative to other locations in the United States. Our current projects are located near or within a reasonable distance from several major interstate and intrastate natural gas pipelines with available capacity that we believe will be sufficient to supply the feed gas required for our projects. We believe these project sites are well-placed and allow us to access liquid and robust natural gas trading areas and obtain competitively priced natural gas for our customers. Our current project portfolio offers geographic diversification within Louisiana. The Calcasieu Project, the CP2 Project and the CP3 Project are located at or near the mouth of the Calcasieu Ship Channel, and the Plaquemines Project and the Delta Project are located approximately 300 miles east and are sited next to the Mississippi River, each of which provides ready access to our facilities from the Gulf of Mexico. Since they are located at or near the mouth of the Calcasieu Ship Channel, the Calcasieu Project, the CP2 Project and the CP3 Project sites’ geography also allow for faster entry into and exit from our berthing docks relative to many other facilities in the region. Our current projects are also located in close proximity to major population centers, providing ease of access for workers and transportation of materials. The Calcasieu Project and Plaquemines Project sites also benefit from full road and water access, and buffer lands to facilitate deliveries and serve as laydown areas, and we expect sites of the CP2 Project, the CP3 Project and the Delta Project to benefit from the same access and buffer lands. We believe our current project sites provide significant opportunities for bolt-on expansions that would benefit from pre-existing plant facilities and related infrastructure (such as common pipe racks, marine offloading facilities and perimeter walls). Moreover, we believe Louisiana is a favorable legal, regulatory and political jurisdiction for our projects.

 

   

LNG shipping and regasification capabilities to supply new customers and to support existing customers. We are assembling a fleet of at least 11 LNG tankers to provide additional optionality to spot and term customers and to service contracts with transportation or delivery components. We have also acquired firm regasification facility capacity at the Grain LNG terminal, Europe’s largest LNG regasification terminal, in the United Kingdom to import 42 LNG cargos per year from approximately 2029 until 2045 (apart for a limited period). Additionally, we have secured approximately 1 mtpa of LNG regasification capacity at the new Alexandroupolis LNG receiving terminal in Greece for five years, beginning in 2025, which equates to approximately 12 cargos annually. We believe that such shipping and regasification capabilities will support our ability to optimize LNG marketing, sales, and logistics to reach new markets and customers.

 

   

Experienced management team aligned with stakeholders.

 

   

Industry-leading team. Our management team possesses deep experience across all parts of the LNG industry with a proven development and operational track record. We believe that the collective quality and experience of our team, coupled with our relationships with our contractors, customers and consultants, enable us to move quickly to continue to take advantage of the North American LNG market opportunity. Further, as of September 30, 2024, we have assembled a broader team of over 1,400 employees globally.

 

   

Exemplary safety record. Notwithstanding the rapid construction progress that we have achieved, the Calcasieu Project and Plaquemines Project have maintained exemplary safety records. Our projects have substantially outperformed the national average of a 1.9 Total Recordable Incident Rate, or TRIR, for 2023, which represents US Bureau of Labor Statistics Heavy Construction Industry recordable incidents per one hundred workers per year. On average, our safety record exceeds the industry average by over ten times with an aggregate TRIR of 0.17 for approximately

 

181


Table of Contents
 

84.5 million hours of work on an aggregate basis as of September 30, 2024. As of September 30, 2024, the Calcasieu Project executed approximately 25.1 million work hours with a TRIR of 0.10 and the Plaquemines Project executed approximately 59.4 million work hours with a TRIR of 0.19.

 

   

Committed to environmental and community initiatives. Our management team is committed to an environmentally sound and community-friendly approach to the development and operation of our projects in conjunction with our key stakeholders. We aim to establish close relationships with the communities where our projects are located by fueling local economic growth, job creation, and skills training, while also engaging in wetlands restoration work. In addition, we have decided to use environmentally-sensitive design features (e.g., electrically-driven motors, air cooling throughout the projects, combined cycle power, and state of the art, full containment storage tanks which seek to eliminate methane release from stored LNG), and are pursuing an initiative to develop certain CCS facilities for our projects.

Our competitive strengths are subject to several risks and competitive challenges. Please read “Risk Factors” and “—Competition.”

Our Business and Growth Strategies

Since our founding in 2013, we have grown rapidly from a two-person company into the formidable energy market disruptor we are today. As of September 30, 2024, we employ over 1,400 people globally and are commissioning, constructing, and developing five natural gas liquefaction and export projects. We also now own or lease or have an option to own or lease nearly 6,000 acres of strategically located land in Louisiana, much of which benefits from significant deep-water frontage. Although we have a limited operating history and did not generate any proceeds prior to 2022, as of September 30, 2024, we have raised approximately $54 billion of capital and generated approximately $19.6 billion in gross proceeds from sales of commissioning cargos, resulting in approximately $14.2 billion of net proceeds. We have also executed 39.25 mtpa of post-COD SPAs as of September 30, 2024, and expect total contracted revenue of approximately $107 billion over the life of such SPAs. Notwithstanding these accomplishments, we are acutely focused on further growth and plan on pursuing the following three core drivers to expand our scale, profitability and impact on the global energy industry.

 

   

Develop, Construct and Operate New LNG Facilities – In addition to the Calcasieu Project and Plaquemines Project, which are undergoing construction and commissioning activities, we are currently developing, permitting, and advancing three projects: the CP2 Project, the CP3 Project and the Delta Project. Based on our success developing, permitting, financing and constructing the Calcasieu Project and the Plaquemines Project, we are confident in our ability to execute these additional projects and expect each facility to increase the cash proceeds we generate from LNG sales over time in a compounding fashion due to the following factors:

 

   

Rapid Return of Capital Enables Parallel Project Development – Unlike most industrial project developers who must wait years to recoup invested capital, our innovative approach to development allows us to generate cash proceeds from commissioning cargos at our projects which can potentially surpass the total costs of the projects prior to COD. Further, this accelerated return profile can also allow us to shift capital from one project under construction to a subsequent project, enabling us to develop multiple projects in parallel. In the case of the CP2 Project, we plan on utilizing cash proceeds from the Calcasieu Project and the Plaquemines Project to fund a substantial portion of construction.

 

   

Optimized LNG Sales – By recycling cash proceeds from one project to fund our subsequent projects, we aim to reduce our need for a critical mass of long-term SPAs for future projects (including the CP2 Project, CP3 Project and Delta Project), which are predominantly lower priced than short- and medium- term SPAs and typically required to support traditional project financing. Any production capacity from our projects that is not otherwise committed can be sold on a short-, medium- or long-term basis, including on a spot basis, providing

 

182


Table of Contents
 

flexibility to optimize the pricing for such capacity and allowing us to balance profit, duration and risk. As a result, while the Plaquemines Project and the CP2 Project are both designed as 20 mtpa nameplate capacity facilities, we expect the cash proceeds generated by the optimized cash proceeds at the CP2 Project to exceed the substantial LNG sales at the Plaquemines Project. We believe this virtuous cycle will compound with subsequent projects.

 

   

Bolt-On Expansions

 

   

A distinctive benefit of our unique design is the ability to flexibly and economically expand liquefaction capacity by adding additional factory-made liquefaction trains and installing them at our existing projects. Bolt-on expansions were contemplated in the initial design and siting of our facilities. Such expansions benefit from substantial redundancy to support additional production capacity.

 

   

We intend to pursue these opportunities in the future and believe that we have the ability to add up to a total of approximately 35.3 mtpa of bolt-on expansion capacity across the Calcasieu Project, the Plaquemines Project, the CP2 Project, and the Delta Project as outlined below. No such expansions are currently contemplated at the CP3 Project due to its considerable 42.0 mtpa expected peak production capacity.

 

   

We aim to self-fund these expansions, reducing our reliance on lower-priced, longer-term contracts that are typically required to support traditional project financing. This strategy enables us to sell the production capacity from any such expansions on a short-, medium- or long-term basis, including on a spot basis, thereby providing flexibility to continually optimize the pricing for such capacity based on market conditions.

 

LOGO

 

(1)

Targets based on, among other things, anticipated timeframes for the receipt of certain regulatory approvals as described in “—Governmental Regulation.”

(2)

Anticipated based on capacity, scale, location and infrastructure. Subject to regulatory approval, among other things, and may change based on design considerations, regulatory review process, engagement with contractors, and other factors.

(3)

Potential bolt-on expansion opportunity based on facility capacity, scale, location and infrastructure. Subject to regulatory approval, among other things, and may change based on design considerations, regulatory review process, engagement with contractors and other factors. Figures are rounded.

 

   

Vertical Integration and Opportunistic Investment

 

   

In addition to our core business, our liquefaction and export projects, we regularly evaluate complementary businesses that have the potential to strengthen our vertical integration, drive growth and support margin expansion. We have already engaged in substantial activities to establish complementary gas transportation, LNG tanker and regasification business lines that we plan to leverage in connection with our core assets.

 

183


Table of Contents
   

Beyond our LNG facilities under development, the bolt-on expansions, and complementary businesses described above, we consistently explore opportunities, both domestic and international, to develop or acquire other LNG projects and further grow our footprint. We believe our design and approach are adaptable and exportable, providing us ample opportunities, both domestically and internationally, beyond our current development pipeline.

 

LOGO

Our Liquefaction and Export Projects and Key, Complementary Assets

In the subsections that follow, we provide a detailed description of our core business—our liquefaction and export projects—and our key, complementary assets along the energy supply chain.

Our Liquefaction and Export Projects

At a high-level, LNG facilities require (i) an input of natural gas, (ii) pre-treatment plants to remove impurities from the natural gas, such as water, CO2, mercury, benzene, and other heavy molecules, that would disrupt or damage other equipment required to produce LNG, (iii) liquefaction plants to supercool the gas and convert it into LNG, (iv) LNG storage tanks to collect and store the LNG prior to loading into LNG tankers for export, (v) deep water access, or frontage, with a jetty and marine berth to load LNG onto LNG tankers, (vi) a power plant or access to the electricity grid to provide the significant amount of electricity required to operate the foregoing systems and equipment, and (vii) extensive “balance of plant” facilities, including piping and piperacks to interconnect, protect, and support the foregoing systems and equipment.

The traditional approach to developing large-scale LNG facilities (i.e., 10 mtpa or more) involves very large, highly customized, stick-built projects consisting of two to three liquefaction trains, each with a nameplate capacity of 4-6 mtpa, that are constructed almost entirely onsite by vast workforces. Due to the size of these liquefaction trains, incremental capacity at traditional LNG facilities generally can only be added in lump-sum, step-function expansions that often require significant investment in the corresponding balance of plant as well as additional land. In effect, expansions of such facilities become projects unto themselves and lose their marginal cost advantage over new build facilities. In addition, many of these large, international, stick-built projects are built in remote locations far away from concentrated sources of experienced construction workforces, adding to their lengthy construction and execution timelines.

Our company was established with the goal of pioneering a new, mid-scale, factory-made liquefaction train configuration, paired with our unique owner-led construction and risk management approach to construct LNG facilities, that aims to minimize EPC scope, optimize the construction schedule to produce LNG earlier in construction, lower costs, and increase reliability. Wherever possible, we seek to leverage the benefits of factory-built systems and limit the amount of stick-built or other on-site fabrication. Given our unique project configuration (which includes many mid-scale liquefaction trains, which are delivered and installed sequentially), it is necessary to commission and test our LNG facilities sequentially over a longer period of time than traditional LNG facilities with substantially fewer,

 

184


Table of Contents

larger-size liquefaction trains. This occurs through a longer commissioning period where our modules and key equipment, and various discrete systems are installed and integrated in parallel with ongoing construction activities. Our modules and key equipment undergo a comprehensive commissioning program, which includes performance testing of individual components and, subsequently, of the entire, fully built facility. Each of our liquefaction and export facilities includes certain key, standardized, modular equipment that follows our “design one, build many approach,” which provides for significant redundancy and interoperability throughout the facility. This key equipment includes our liquefaction trains, gas pre-treatment systems, power island systems (which are self-sufficient power plants that do not rely on electricity from the electricity grid), LNG storage tanks, and marine loading berths. As part of our construction approach, we aim to construct and commission portions of the facility in various liquefaction production systems that consist of liquefaction, power, natural gas pre-treatment systems and certain other facilities that are required to produce LNG. For example, at a given 20 mtpa project, although there can be no assurance as to the actual timeline for any particular project, we aim for an overall construction timeline, across two phases, of approximately 60 months from FID, during which we aim to install, test, and complete six distinct liquefaction production systems (each consisting of two or more liquefaction blocks, with a contractual performance testing period of at least 30 days each). Once a phase or the entire project is complete, we plan to conduct an additional comprehensive 90-day reliability test. We aim to utilize this repeatable configuration across the projects that we develop to continually refine and optimize our LNG production operations.

Our liquefaction trains, gas pre-treatment systems, and power island systems are primarily manufactured and assembled off-site in factory settings. Our liquefaction trains are manufactured by Baker Hughes and are each designed with a nameplate capacity of 0.626 mtpa. Nameplate capacity measures the minimum guaranteed operating performance thresholds guaranteed by the equipment providers. We also aim to construct and maintain LNG facilities that are capable of producing excess capacity, in most cases, of at least 30% of their guaranteed nameplate capacity. We deploy our liquefaction trains in blocks, consisting of, among other things, two liquefaction trains, a cold box (which is used to lower the temperature of natural gas to the point at which it liquefies), and an electrically driven compressor. Our gas pre-treatment systems utilize processing technology from UOP LLC, or UOP, a subsidiary of Honeywell International Inc., or Honeywell International, and are purchased in quantities designed to support production capacities well in excess of our projects’ production capacity. Our power island systems are self-sufficient power plants that do not rely on electricity from the grid and are purchased from Baker Hughes. Depending on the size of the facility, the power island systems consist of one or more nominal 620 MW (720 MW at peak) inside-the-fence, air-cooled combined cycle gas-fired power plant (with five gas turbine generators and two steam turbine generators) and one or more nominal 23 MW LM2500 gas turbines that supports frequent cycling and provide back-up power and black start capabilities. Our power equipment is manufactured off-site by General Electric.

Our LNG storage tanks and marine loading berths are constructed on site by specialized contractors. Our LNG storage tanks are constructed by CB&I at an industry leading pace and are designed to be among the largest LNG tanks in the industry at 200,000 m3. We also design our facilities with multiple marine loading berths that are interoperable with our LNG storage tanks and are capable of loading one or more LNG tankers in parallel.

We design our facilities to incorporate supplemental capacity throughout the facility to safeguard the availability of our mid-scale train configuration with a goal of achieving high levels of redundancy and flexibility, which we believe will increase our availability and production. For example, redundancy is present in our gas pre-treatment systems, as each pre-treatment unit is designed to meet approximately 50% of our production requirements – for every 10 mtpa of nameplate capacity, we have approximately 15 mtpa of pre-treatment capacity. Further, we build enough 200,000 m3 LNG storage tanks at each of our projects to service up to 150% of its nameplate capacity. We combine this redundancy with interoperability that allows us to load LNG from any individual liquefaction train into any LNG storage tank for the relevant facility. Each tank in turn can load a cargo via any jetty. Once complete, we believe this equipment and our “design-one, build-many” facility design has the potential to provide greater operational redundancy and availability, reducing planned and unplanned downtime and enabling us more to reliably deliver LNG to our customers, and to increase production from our existing equipment. The benefits of our “design one, build many” approach extend further, as our two existing projects can provide our future projects with a source of interchangeable parts and a venue to train

 

185


Table of Contents

personnel on identical equipment. The ability to pool resources across our projects will increase our operating leverage and may augment our earnings through reduced fixed and variable operating expenses.

Our projects are also designed to benefit from significant potential bolt-on expansion capacity, or expansions to our existing project sites beyond our current targets, that we intend to explore in the future. Subject to receiving the requisite regulatory approvals, we believe our projects offer potential optimization, increased capacity and expansion opportunities. In particular, we believe our current project sites provide attractive opportunities for potential bolt-on expansion (for example, by adding additional liquefaction trains, subject to regulatory approvals) beyond the current combined expected peak production capacity of 143.8 mtpa, potentially at reduced construction costs. We intend to pursue these bolt-on expansion opportunities in the future and believe that we have the potential to add approximately 35.3 mtpa in total across the Calcasieu Project, the Plaquemines Project, the CP2 Project, and the Delta Project as outlined below based on current, actual and anticipated project design, as applicable, and subject to regulatory approval. These expansion opportunities do not contemplate any expansion at the CP3 Project due to its considerable 42.0 mtpa expected peak production capacity. We believe any such incremental equipment would benefit from pre-existing plant redundancies (such as in our power island and gas pre-treatment equipment) and related infrastructure (such as marine facilities, LNG storage tanks and perimeter walls), though additional plant components will likely be required and there are constraints on our existing equipment being able to be used towards the bolt-on expansion. We expect that increases to LNG production from either optimizing existing equipment and systems or incremental bolt-on expansion may significantly lower the net cost of liquefying LNG and increase profits as LNG is sold more attractively into the commodity markets.

Below is a geographic overview of our five current projects, which is followed by a detailed description of each project.

 

LOGO

 

186


Table of Contents

Calcasieu Project

 

 

Calcasieu Project

Project location:

    

Site

   Approximately 432 acres in Cameron Parish, Louisiana

Property rights

   Ground leases for 30 years, with options to extend to 70 years

Deep-water frontage

   Approximately 1.0 mile

Project design:

    

Expected nameplate capacity

   10.0 mtpa

Expected peak production capacity

   Up to 12.4 mtpa

Potential bolt-on expansion incremental capacity

   Up to 4.5 mtpa(1)

Liquefaction system

   18 liquefaction trains

LNG storage

   2 × 200,000 cubic meter cryogenic LNG storage tanks

Power supply

   1 power island system (with a capacity of 620 MW nominal / 720 MW peak and consisting of 5 gas turbine generators and 2 steam turbine generators along with related equipment)

Gas pre-treatment system

   3 units, each designed to support 50% of the expected nameplate capacity (1 redundant unit)

Berths

   2 berths, each designed to accommodate vessels of up to 185,000 cubic meters in capacity

Lateral pipeline

   Approximately 24-mile long lateral

Key permits:

    

FERC approval

   12.4 mtpa (February 2019 and September 2023)

DOE approval – FTA Nations

   12.4 mtpa (September 2013 and April 2022)(2)

DOE approval – Non-FTA Nations

   12.0 mtpa (March 2019)(2)(3)

Project timeline:

    

Final investment decision / financial closing

   August 2019

First LNG production

   January 2022

Targeted COD

   End of March 2025

 

(1)

Potential bolt-on expansion opportunity based on facility capacity, scale, location and infrastructure. Subject to regulatory approval, among other things, and may change based on design considerations, regulatory review process, engagement with contractors and other factors.

(2)

Cumulative exports to FTA Nations and Non-FTA Nations cannot exceed the permitted capacity as authorized by the FERC.

(3)

Our request to increase the authorized level of exports to Non-FTA Nations from 12.0 mtpa to 12.4 mtpa is still pending. See “—Governmental Regulation—DOE Export Authorizations—Calcasieu Project.”

Project Description

The Calcasieu Project is a liquefaction and export facility in the commissioning phase, with an expected nameplate capacity of 10.0 mtpa and an expected peak production capacity of 12.4 mtpa, located on approximately 432 acres of land in Cameron Parish near the Gulf of Mexico and south of Lake Charles, Louisiana, with approximately one mile of deepwater frontage on the east side of the Calcasieu Ship Channel.

The Calcasieu Project consists of 18 mid-scale, factory-built liquefaction trains (9 integrated single mixed refrigerant blocks) and support facilities. The Calcasieu Project also includes three gas pre-treatment units (each designed to support approximately 50% of the gas pre-treatment needs of the Calcasieu Project), two 200,000 m3 full containment LNG storage tanks and two marine loading berths rated at 12,000 m3/hr. The Calcasieu Project is powered by a newly constructed nominal 620 MW (720 MW at peak) inside-the-fence, air-cooled combined

 

187


Table of Contents

cycle gas-fired power plant, which is dedicated solely to providing electricity to the Calcasieu Project and supporting facilities. The power plant is complemented by a nominal 23 MW LM2500 gas turbine that supports frequent cycling and provides back-up power and black start capabilities. An approximately 24-mile long lateral pipeline connects the liquefaction plant to the existing interstate and intrastate natural gas pipeline system to receive feed gas for liquefaction and for the power plant.

Project Site Real Estate

Our existing ground leases with various landowners covering the land on which the Calcasieu Project and our marine offloading facilities for the Calcasieu Project are located allow us to extend the initial lease period of 30 years for up to four additional ten-year terms, up to 70 years in the aggregate. See “—Properties” for more information.

Project Construction and Commissioning

We made our FID for the project in August 2019, loaded our first LNG cargo for sale in March 2022, and all 18 liquefaction trains were capable of producing initial quantities of LNG by July 2022.

The Calcasieu Project was constructed pursuant to several key contracts, including an EPC contract, or the Calcasieu EPC Contract, with Kiewit Louisiana Co., or Kiewit. Under the Calcasieu EPC Contract, Venture Global was responsible for executing or directly managing significant scopes of work. The work performed by Kiewit included contributions to the design, engineering, erection, and integration of the balance of the facility not otherwise provided by Venture Global’s vendors – who delivered the majority of modules and key equipment for the project. Kiewit’s work also included facilitating the passage of performance tests for the liquefaction trains and power plant. See “—EPC Contracts,” for more information.

Venture Global directly contracted with other contractors to design and manufacture the main operating components of the facility. Baker Hughes fabricated the mid-scale, factory-built liquefaction trains and also provided, through a General Electric subsidiary, a comprehensive combined cycle gas-fired power plant for the project. All equipment provided by Baker Hughes was delivered to the site and installed or incorporated in the facility. Weeks Marine, a proven leader in maritime construction, constructed a perimeter wall that is designed to fully enclose (along with the marine-side berm) and protect the project as well as two marine loading berths. CB&I LLC, or CB&I, a subsidiary of McDermott International, Ltd., constructed the two LNG storage tanks. UOP provided the natural gas pre-treatment equipment which was delivered to the site and installed or incorporated in the facility. WHC LLC, or WHC, constructed the TransCameron Pipeline. Baker Hughes, Weeks Marine, CB&I and UOP provided Venture Global with guarantees of the performance of the components they provided and assumed obligations to “make good” on certain deficiencies, which generally entails an obligation by such contractors, at their own cost, to ensure performance meets certain guaranteed minimums.

Construction of the Calcasieu Project is substantially complete and the project is currently undergoing a multi-faceted commissioning program to complete the facility’s components, bring them to design specification and establish reliable and safe facility-wide operating conditions and to prepare for the commencement of lender-required performance reliability testing. Significant work related to commissioning, carryover completions, and rectification is ongoing and includes remedying unexpected challenges with equipment reliability identified during the first-time implementation of our innovative design and configuration, and reliability testing. We believe such work will need to be completed before certain components operate as intended and the facility can be fully commercially operable, and COD can occur. On March 28, 2023, we submitted to FERC an update regarding commissioning, certain identified reliability challenges, and needed repairs and replacements, which we are working to complete in compliance with FERC’s regulatory requirements. Specifically, we are conducting substantial remediation work on the heat recovery steam generators, or HRSGs, of the power island system where the manufacturer of such equipment, General Electric, implemented a change in method of fabrication that has led to substantial leaking that was identified during commissioning tests. As part of the remediation work, replacement parts for the HRSGs have been manufactured by our contractor by utilizing a proven fabrication

 

188


Table of Contents

method, which we have explicitly required to be used for the Plaquemines Project and the CP2 Project, and which we expect to require for each project or phase thereof for which we have not executed a power island system purchase order. Among the other ongoing rectification work, our gas pre-treatment units have underperformed and have been unable to pass required performance tests. We continue to engage in remediation efforts with UOP to improve the pre-treatment operations to attain the designed levels of performance and redundancy and pass such required performance tests.

Given the ongoing significant commissioning and remediation work, we are targeting to complete all remediation work and achieve COD at the end of March 2025 once the project has completed its commissioning process and testing and is capable of safely and reliably producing its designed nameplate levels of LNG volumes.

As of September 30, 2024, the Calcasieu Project executed approximately 25.1 million work hours with a TRIR of 0.10. This safety performance far exceeds the national average for the industry of 1.9 for 2023.

Commissioning LNG Sales

Due to our unique project configuration (which includes many mid-scale liquefaction trains, which are delivered and installed sequentially) and development approach, it is necessary to commission and test our LNG facilities sequentially over a longer period of time than traditional LNG facilities with substantially fewer, larger-size liquefaction trains. This important reliability and technical requirement has resulted in the production of LNG starting earlier in the construction schedule than at traditional LNG facilities, and in far greater quantities – requiring us to produce a substantial number of commissioning cargos at the Calcasieu Project. Despite the longer than expected commissioning process at the Calcasieu Project due to certain unexpected challenges with equipment reliability that we are in the process of remediating, as of September 30, 2024, the Calcasieu Project had loaded and sold 342 LNG commissioning cargos and received approximately $19.6 billion in gross proceeds (approximately $14.2 billion in net proceeds after deducting net cash paid for natural gas, which primarily includes the net cost of purchasing and transporting feed gas) from such commissioning cargos. A portion of such proceeds are held in cash reserve accounts pursuant to our project financing arrangements and reflected as restricted cash in our financial statements at the Calcasieu Project in an amount we expect to be necessary to complete the project and achieve COD under the Calcasieu Foundation SPAs. As of September 30, 2024, we had an aggregate of $567 million of restricted cash in reserve accounts at the Calcasieu Project.

 

189


Table of Contents

Post-COD Contracts and Excess LNG Sales

We have entered into six 20-year take-or-pay, post-COD SPAs, or the Calcasieu Foundation SPAs, on an FOB basis, which means that the title to the LNG will transfer at the time our customers take delivery at our facilities. Consequently, our customers under our FOB SPAs will bear the risk of loss during transport and the cost of shipping the LNG cargo. The Calcasieu Foundation SPAs as summarized below equate to approximately 8.5 mtpa of LNG, which is approximately 85% of the project’s expected nameplate capacity of 10.0 mtpa. The majority of these offtakers have investment grade credit ratings and are among the industry’s strongest financial credits.

 

LOGO

The obligation to make LNG available under the Calcasieu Foundation SPAs commences from the occurrence of COD, which is an identical requirement for all six SPAs and a typical construct within the LNG industry. Under these six SPAs, customers will purchase LNG from us for a price consisting of a fixed facility charge (a portion of which is subject to an annual adjustment for inflation) per MMBtu of LNG, plus a variable commodity charge equal to 115% of Henry Hub per MMBtu of LNG. In certain circumstances, customers may elect to cancel or suspend deliveries of LNG cargos, but they will still be required to pay the fixed fee (but not the variable commodity charge) with respect to contracted volumes that are not delivered as a result of such cancellation or suspension. The Calcasieu Foundation SPAs and related contracted volumes are not tied to any specific liquefaction trains at the Calcasieu Project. To the extent of any shortfall in supply, we will pay the applicable counterparty to an SPA an amount for shortfall based on: (a) (i) the replacement price for LNG or, in the event a replacement quantity cannot be purchased, the market price of LNG at such time at the cargo’s originally scheduled destination, minus (ii) the contract sales price plus (b) costs (including transportation costs) incurred by such counterparty due to such shortfall, plus (c) costs incurred by such counterparty associated with idling an LNG tanker scheduled to load the shortfall quantity, minus (d) cost savings realized by such counterparty due to the shortfall. This requirement to financially address shortfalls over the 20-year life of the Calcasieu Foundation SPAs underpins the focus on redundancy and reliability to be demonstrated as part of the commissioning phase of construction, prior to achieving COD.

The Calcasieu Foundation SPAs include termination rights in favor of the customer if, among other things, COD did not occur by March 2024, as may be extended in certain circumstances (including, among other things, in connection with a force majeure event). As a consequence of the occurrence of one such force majeure event, as further described below, the deadline for COD in such SPAs would be extended and we currently anticipate that such customers will not be entitled to terminate as a result of failure to designate COD until June 2025. We have notified all of our customers under the Calcasieu Project post-COD SPAs of the anticipated delay to COD,

 

190


Table of Contents

indicating that such delay results from a force majeure event. All of such customers have questioned whether the delay constitutes a force majeure event under the contract, in which case they would have a right to terminate their SPAs, generally for a limited duration of time, if COD did not occur by March 2024. For more information see “Risk Factors—Risks Relating to Our Business—Our customers or we may terminate our SPAs if certain conditions are not met or for other reasons.” As we continue to commission the facility, we aim to continue to produce commissioning cargos of LNG for export in accordance with all regulatory requirements and subject to the above described HRSG and gas pre-treatment remediation work and other repairs being conducted while the site is made ready for reliability testing.

In addition to such 20-year Calcasieu Foundation SPAs, we have entered into a fixed-price three-year take-or-pay SPA for 1 mtpa of the Calcasieu Project’s expected nameplate capacity with Unipec (a subsidiary of Sinopec) and a fixed-price five-year take-or-pay SPA for 0.5 mtpa of the Calcasieu Project’s expected nameplate capacity with CNOOC Gas and Power Singapore Trading & Marketing Pte. Ltd. These shorter-term, post-COD SPAs include similar terms and conditions as the long-term Calcasieu Foundation SPAs and provide supplemental, firm contracted revenues for the benefit of the project. Following expiration of these shorter-term, post-COD SPAs, the corresponding 1.5 mtpa of the expected nameplate capacity can be recontracted by us at our discretion under short-, medium- or long-term contracts, providing the flexibility to optimize pricing and capture additional revenue for the project in future periods.

We expect that any excess LNG produced by the Calcasieu Project above the nameplate capacity of 10.0 mtpa will be sold to VG Commodities under the applicable Intercompany Excess Capacity SPA. LNG sold under this Intercompany Excess Capacity SPA can, to the extent not previously committed to third parties, be resold to third party customers at our discretion under short-, medium- or long-term contracts, providing the flexibility to optimize pricing, which is typically higher in the short- to medium-term market, and capture additional revenue on an ongoing basis after COD.

A portion of the Calcasieu Project’s excess capacity that is sold to VG Commodities is already contracted to be resold. VG Commodities is party to an LNG sales and purchase agreement, or the VG Commodities BP SPA, with BP Gas Marketing Limited, or BP, pursuant to which, once COD occurs under the applicable Intercompany Excess Capacity SPA, VG Commodities has contracted to resell at least 50% of the LNG generated by the Calcasieu Project in excess of its nameplate capacity (subject to an annual cap at the option of the buyer). The VG Commodities BP SPA is structured as a 20-year, FOB sales contract, under which BP is required to pay VG Commodities a purchase price for LNG delivered to BP based on a simulated net-back price, which is designed to reflect a profit margin (after deducting related costs) realized from downstream sales of LNG. However, in certain cases, including if an event of default by VG Commodities occurs under the VG Commodities BP SPA, BP is entitled to an assignment of VG Commodities’ rights under the relevant Intercompany Excess Capacity SPA.

 

191


Table of Contents

Plaquemines Project

 

 

Plaquemines Project    Phase 1    Phase 2

Project location:

         

Site

   Approximately 630 acres in Plaquemines Parish, Louisiana

Property rights

   Ground lease for 30 years, with options to extend to 70 years

Deep-water frontage

   Approximately 1.3 miles

Project design:

         

Expected nameplate capacity

   13.3 mtpa    6.7 mtpa

Expected peak production capacity

   Up to 27.2 mtpa(1)

Potential bolt-on expansion incremental capacity

   Up to 8.9 mtpa(2)

Liquefaction system

   12 blocks (24 liquefaction trains)    6 blocks (12 liquefaction trains)

LNG storage

   2 × 200,000 cubic meter cryogenic LNG storage tanks    2 × 200,000 cubic meter cryogenic LNG storage tanks

Power supply

   2 power island systems (each with a capacity of 620 MW nominal / 720 MW peak and consisting of 5 gas turbine generators and 2 steam turbine generators along with related equipment)

Gas pre-treatment system

   4 units (1 redundant unit)    2 units (1 incremental redundant unit)

Berths

   2 berths, each designed to accommodate vessels up to 200,000 cubic meters in capacity    1 berth, designed to accommodate vessels up to 200,000 cubic meters in capacity

Lateral pipelines

   Two laterals (one approximately 15-mile long lateral and one approximately 12-mile long lateral)

Key permits:

         

FERC approval

   24.0 mtpa (September 2019)(1)

DOE approval – FTA Nations

   27.2 mtpa (June 2022)(3)

DOE approval – NON-FTA Nations

   24.0 mtpa (October 2019)(1)

Project timeline:

         

Final investment decision / financial closing

   May 2022    March 2023

First LNG production

   December 2024

Targeted COD

   Q3 2026    Q2 2027

 

(1)

Our request to increase the authorized production capacity and authorized level of exports to Non-FTA Nations from 24.0 mtpa to 27.2 mtpa is still pending. See “—Governmental Regulation—Federal Energy Regulatory Commission (FERC)—Plaquemines Project” and “—Governmental Regulation—DOE Export Authorizations—Plaquemines Project.”

(2)

Potential bolt-on expansion opportunity based on facility capacity, scale, location and infrastructure. Subject to regulatory approval, among other things, and may change based on design considerations, regulatory review process, engagement with contractors and other factors.

(3)

Cumulative exports to FTA Nations and Non-FTA Nations cannot exceed the permitted capacity as authorized by the FERC.

 

192


Table of Contents

Project Description

We are in an advanced stage of construction for the Plaquemines Project, which is being built in two phases, with an expected nameplate capacity of 20.0 mtpa and, subject to certain regulatory approvals, an expected peak production capacity of 27.2 mtpa, located on approximately 630 acres of land in Plaquemines Parish, with approximately 1.3 miles of deep-water frontage on the Mississippi River. Phase 1 of the project is expected to have a nameplate capacity of 13.3 mtpa and is in an early stage of commissioning, while construction remains ongoing. Phase 2 is expected to have a nameplate capacity of 6.7 mtpa. We currently have applications pending with the United States Federal Energy Regulatory Commission, or FERC, and the United States Department of Energy, or DOE, that, if approved, would increase the permitted production capacity and authorized export capacity from 24.0 mtpa to 27.2 mtpa.

The liquefaction system for the Plaquemines Project facility will include 36 mid-scale, factory-built liquefaction trains (18 integrated single mixed refrigerant blocks) and support facilities. As with the Calcasieu Project, each block will contain two liquefaction trains. For each 10 mtpa of its nameplate capacity, the facility will also include three natural gas pre-treatment units to remove water and acid gases from feed gas prior to liquefaction, and two 200,000 cubic meter cryogenic LNG storage tanks. The marine facilities for Phase 1 include two LNG berthing docks that would accommodate vessels of up to 200,000 cubic meters in capacity, one full nominal 620 MW (720 MW peak) inside the fence, air-cooled combined cycle gas fired power plant and a portion of the power equipment for a second nominal 620 MW power plant. Both pipeline laterals for the combined project have been built as part of Phase 1. Phase 2 adds a third LNG berthing dock and additional inside the fence, air-cooled combined cycle gas fired power capacity. The two power island systems are complemented by two nominal 23 MW LM2500 gas turbines that support frequent cycling and provide back-up power and black start capabilities. Once complete, we believe this technology and our facility design will provide greater operational redundancy and availability, reducing planned and unplanned downtime, lower emissions and enable us to reliably deliver LNG to our customers.

Project Site Real Estate

In July 2021, we entered into a 30-year lease with the Plaquemines Port Harbor and Terminal District, covering the land on which the project is located. This lease may be extended at our option for up to four additional 10-year terms, up to 70 years in the aggregate.

Project Construction and Commissioning

We made our FID for Phase 1 in May 2022 and our FID for Phase 2 in March 2023. As of September 30, 2024, construction of the Plaquemines Project was approximately 86% complete, based on completion of the 20.0 mtpa expected nameplate capacity, with Phase 1 93% complete and Phase 2 73% complete.

The Plaquemines Project is being constructed pursuant to two EPC contracts, one per phase, or the Plaquemines EPC Contracts, that we entered into with KZJV, LLC, or KZJV, a limited liability company that is owned by KBR EPC Member and Zachry Industrial. Under the Plaquemines EPC Contracts, Venture Global is responsible for executing or directly managing significant scopes of work. We issued the notice to proceed, or NTP, under the Plaquemines EPC Contract for Phase 1 in May 2022. The NTP for Phase 2 was issued in March 2023. See “—EPC Contracts—Plaquemines EPC Contracts” for additional information on the Plaquemines EPC Contracts.”

Baker Hughes, UOP and CB&I are each providing and constructing the mid-scale, factory-built liquefaction trains and power island systems, the pre-treatment system, and storage tanks, respectively, similar to their scope and terms for the Calcasieu Project. See “—Calcasieu Project” above for more information. As of September 30, 2024, twenty-four of the thirty-six liquefaction trains were delivered to the site. Other recent procurement and construction milestones included receiving all major power equipment for the project on site, receiving each natural gas pre-treatment module required for Phase 1 on site, achieving final completion on the first of four LNG storage tanks and achieving substantial completion for all three LNG berthing docks. Sunland Construction Inc. was responsible for constructing the Gator Express pipeline that connects the LNG facility to interstate pipelines. The Gator Express pipeline achieved mechanical completion in October 2023 and its laterals were placed in service in May 2024 and December 2024.

 

193


Table of Contents

We currently estimate that the total project costs for the Plaquemines Project will be approximately $22 billion to $23 billion, including EPC contractor profit and contingency, owners’ costs and financing costs. Of the total project costs for the Plaquemines Project, approximately $17.7 billion had been paid for as of September 30, 2024. Our estimated total project cost remaining is based upon our project cost experiences with the Calcasieu Project and with the Plaquemines Project to date and reflects the current inflationary environment. However, the costs to complete the Plaquemines Project have increased in the past, and may increase further in the future, potentially materially, compared to our current estimates as a result of many factors. As a result, the actual project costs for the Plaquemines Project may be materially higher than our current estimates. See “Risk Factors—Risks Relating to Our Projects and Other Assets—Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.”

As of September 30, 2024, the Plaquemines Project had executed approximately 59.4 million work hours with a TRIR of 0.19. This safety performance far exceeds the national average for the industry of 1.9 for 2023.

Commissioning LNG Sales

Although designed to be twice as large as the Calcasieu Project on a nameplate basis, the Plaquemines Project utilizes a similar project configuration and development approach to the Calcasieu Project. In contrast to traditional LNG facilities that are constructed by a single EPC contractor and include substantially fewer, larger-size liquefaction trains, our project design and configuration utilizes pioneering, mid-scale, factory-made liquefaction trains and other discrete systems and equipment, which require an extended commissioning period. Given this longer and gradual commissioning period, which starts with addressing identified operational deficiencies, testing individual components and eventually extends to encompass testing and tuning our entire fully-integrated facilities, we expect to produce a substantial number of commissioning cargos. This production occurs during the period in which additional components of the relevant phase are brought into operation, completed and tested (including, if necessary, performing completion and rectification work to address unexpected performance deficiencies), to ensure the project is completed and achieves the performance levels necessary for stable, reliable long-term operations to supply LNG under the project’s post-COD SPAs. In December 2024, we began to produce LNG at the Plaquemines Project and commenced loading our first commissioning cargo.

Post-COD Contracts and Excess LNG Sales

As of the date of this prospectus, we have entered into twelve 20-year take-or-pay, post-COD SPAs in connection with the Plaquemines Project, or the Plaquemines Foundation SPAs. The Plaquemines Foundation SPAs, as summarized in the chart below, equate to approximately 19.7 mtpa of LNG, which is approximately 98.5% of the project’s expected nameplate capacity of 20.0 mtpa. The majority of these offtakers have investment grade credit ratings and are among the industry’s strongest financial credits.

 

194


Table of Contents

LOGO

The obligation to make LNG available under these SPAs commences from the occurrence of COD, which is bifurcated by Phase 1 or Phase 2, depending on the SPA. All of these SPAs are structured to be delivered on an FOB basis, with the exception of one Phase 1 SPA for 1.2 mtpa, which is structured to be delivered on a DPU basis – requiring us to ship, deliver, and unload LNG to our customer’s designated import facility. The pricing structure and contractual obligations in the Plaquemines Foundation SPAs substantially mirrors the Calcasieu Foundation SPAs. See “—Calcasieu Project” for more information. Similar to the Calcasieu Foundation SPAs, the Plaquemines Foundation SPAs include termination rights in favor of the customer if, among other things, COD does not occur by May 2027 or March 2028 for the Phase 1 and Phase 2 SPA, respectively, as may be extended in certain circumstances (including, among other things, in connection with a force majeure event).

In addition to the Plaquemines Foundation SPAs, we have entered into a short-term, post-COD SPA for 0.3 mtpa of the Plaquemines Project’s expected nameplate capacity with Inpex Energy Trading Singapore Pte. Ltd. on an FOB basis. This shorter-term, post-COD SPA includes similar terms and conditions as the Plaquemines Foundation SPAs and provides supplemental, firm contracted revenues for the benefit of the project. After the expiry of such SPA, such 0.3 mtpa can be recontracted by us at our discretion under short-, medium- or long-term contracts, providing the flexibility to optimize pricing and capture additional revenue for the project.

Any excess LNG produced by the Plaquemines Project above the nameplate capacity of 13.3 mtpa for Phase 1 or above the nameplate capacity of 6.7 mtpa for Phase 2 will be sold to VG Commodities under the applicable Intercompany Excess Capacity SPA (one per phase). LNG sold under such Intercompany Excess Capacity SPAs can, to the extent not previously committed to third parties, be resold to third party customers at our discretion under short-, medium- or long-term contracts, providing the flexibility to optimize pricing and capture additional revenue on an ongoing basis after COD for each of Phase 1 and Phase 2, at price levels that we expect will typically exceed the fixed fee prices secured under the Plaquemines Foundation SPAs.

 

195


Table of Contents

CP2 Project

 

 

CP2 Project   Phase 1   Phase 2

Project location:

Site

  Approximately 1,150 acres in Cameron Parish, Louisiana

Property rights

  Ground leases for 30 years, with options to extend to 70 years

Deep-water frontage

  Approximately 1.0 mile

Anticipated project design:(1)

Expected nameplate capacity

  14.4 mtpa   5.6 mtpa

Expected peak production capacity

  Up to 28.0 mtpa

Potential bolt-on expansion incremental capacity

  Up to 14.0 mtpa(2)

Liquefaction system

  13 blocks (2 liquefaction trains per block)   5 blocks (2 liquefaction trains per block)

LNG storage

  2 × 200,000 cubic meter cryogenic LNG storage tanks   2 × 200,000 cubic meter cryogenic LNG storage tanks

Power supply

  2 power island systems (each with a capacity of 620 MW nominal / 720 MW peak and consisting of 5 gas turbine generators and 2 steam turbine generators along with related equipment)

Gas pre-treatment system

  4 units (1 redundant unit)   2 units (1 incremental redundant unit)

Berths

  2 berths, each designed to accommodate vessels up to 200,000 cubic meters in capacity    

Lateral pipelines

  Two laterals (one approximately 6-mile long lateral and one approximately 85-mile long lateral)

Key permits:

FERC approval

  June 2024 (subject to partial supplemental review)(3)

DOE approval – FTA Nations

  28.0 mtpa (April 2022)

DOE Non-FTA Nations

  Application filed December 2021 (pending approval)

Project timeline:

Targeted final investment decision / financial closing

  Mid-2025  

Mid-2026

Targeted COD

 

Mid-2029

 

Mid-2030

 

(1)

Anticipated based on capacity, scale, location and infrastructure. Subject to regulatory approval, among other things, and may change based on design considerations, regulatory review process, engagement with contractors, and other factors.

(2)

Potential bolt-on expansion opportunity based on facility capacity, scale, location and infrastructure. Subject to regulatory approval, among other things, and may change based on design considerations, regulatory review process, engagement with contractors and other factors.

(3)

The FERC issued its order authorizing the CP2 Project in June 2024. However, on November 27, 2024, FERC issued an order on rehearing that partially “set aside” its prior analysis of the cumulative air impacts of emissions of nitrogen dioxide (NO2) and particulate matter less than 2.5 micrometers (PM2.5) and to prepare a supplemental Environmental Impact Statement concerning that topic and to address it along with certain other air quality issues in a future order that FERC anticipates issuing no later than July 24, 2025. FERC also announced that, due to its initiation of supplemental environmental review, it will not issue authorizations to proceed with construction until FERC issues a further

 

196


Table of Contents
  merits order. Project opponents have also appealed the FERC authorization to the U.S. Court of Appeals for the D.C. Circuit. In response to FERC’s order on rehearing, the D.C. Circuit on December 13, 2024, granted an unopposed motion by FERC to hold the appeal in abeyance, which will delay briefing of the D.C. Circuit appeal. See “Risk Factors—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

Project Description

Our third project, the CP2 Project, is in an advanced stage of engineering, with major procurement work, and off-site manufacturing of key modules and equipment underway. The CP2 Project is designed as a natural gas liquefaction and export facility that will be built in two distinct phases, with an expected nameplate capacity of 20.0 mtpa and an expected peak production capacity of 28.0 mtpa. The project will be located adjacent to the Calcasieu Project on approximately 1,150 acres of land in Cameron Parish, with approximately 1 mile of deep-water frontage on the Calcasieu Ship Channel. Phase 1 of the project is anticipated to comprise 14.4 mtpa nameplate capacity and Phase 2 is anticipated to comprise 5.6 mtpa nameplate capacity.

Project Site Real Estate

In 2019, we entered into a 30-year lease (with extension rights) covering approximately 351 acres of land on which the CP2 Project will be located. In October 2023, we exercised our rights under various option agreements with respect to an additional 718 acres of land on which the CP2 Project will be located or will be adjacent to. These leases have up to four additional ten-year terms, up to 70 years in the aggregate, similar to leases for the Calcasieu Project and the Plaquemines Project. We acquired fee simple ownership to approximately 27 acres of the project site in 2023.

Project Engineering, Procurement, and Construction

We have already completed substantial engineering, procurement, manufacturing and off-site construction work for the CP2 Project in advance of a final investment decision, which remains subject to certain regulatory approvals and market conditions. See “—Governmental Regulation” and “Risk Factors—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

As of September 30, 2024, engineering work for Phase 1 of the CP2 Project was approximately 76% complete and we had spent an aggregate of approximately $3.1 billion of costs for various engineering, procurement, manufacturing, and other activities to support the project. Engineering completion percentage is a key driver of schedule and budget fidelity during project construction and execution. In April 2023, we entered into a liquefaction train system purchase order with Baker Hughes for Phase 1 of the CP2 Project and we issued full NTP in September 2023. In May 2023, we entered into an EPC Contract for construction of Phase 1 of the CP2 Project, or the CP2 Phase 1 EPC Contract, with Worley Field Services Inc., or Worley, and have issued several limited notices to proceed thereunder. See “EPC Contracts—CP2 Phase 1 EPC Contract” for additional information on the CP2 Phase 1 EPC contract. In June 2023, we entered into an engineering, procurement, and construction contract with CB&I for the Phase 1 storage tanks under similar terms as for the LNG tanks built at the Calcasieu Project and Plaquemines Project. We issued certain limited notices to proceed to CB&I in June 2023 and November 2023. In July 2023, we entered into a power island system purchase order with Baker Hughes for Phase 1 of the CP2 Project and we issued full NTP in September 2023. In September 2024, we entered into a power island system purchase order with Baker Hughes for Phase 2 of the CP2 Project and we issued a limited NTP for Baker Hughes to commence certain work in relation thereto. In December 2024, we entered into a liquefaction train system purchase order with Baker Hughes for Phase 2 of the CP2 Project and also issued full NTP thereunder. Additionally, we entered into contracts for several other discrete portions of the facility, including certain natural gas pre-treatment system licensing, engineering, and procurement agreements, with UOP and Burns & McDonnell Engineering Company, Inc., respectively, and an agreement with Cajun Industries, LLC for the construction of the CP2 perimeter wall. We plan to select our remaining engineering, procurement, and construction contractors based on competitive bid procurement processes and strict adherence to requiring the highest quality of work.

 

197


Table of Contents

We expect that the construction, commissioning and operational start-up of the liquefaction plant will be substantially similar to the Calcasieu Project and the Plaquemines Project. However, we anticipate that we will seek to manage additional scopes of work directly at the CP2 Project and the other projects we develop in the future. Specifically, we anticipate that we will perform additional EPCM activities and deploy labor that we recruit to leverage lessons learned and the relationships fostered with construction and fabrication subcontractors while developing the Calcasieu Project and the Plaquemines Project, which we believe will help improve construction efficiency and reduce total costs for the CP2 Project.

We currently estimate that the total project costs for the CP2 Project will range between approximately $27 billion and $28 billion, including EPC contractor profit and contingency, owners’ costs and financing costs, substantially all of which has yet to be funded. Our estimated total project cost is based upon our project cost experiences with the Calcasieu Project and the Plaquemines Project and reflects the current inflationary environment and that the CP2 Project’s pipelines are expected to be longer than the pipelines for the Calcasieu Project and the Plaquemines Project. However, we have not yet entered into an EPC Contract for Phase 2 of the CP2 Project or certain other key contracts for the development and construction of the CP2 Project. As a result, there can be no assurance that we will be able to enter into such contracts on similar terms to those for the Calcasieu Project, the Plaquemines Project, and/or Phase 1 of the CP2 Project, as applicable. In addition, certain regulatory approvals and permits must be obtained on a timely basis in order to construct and operate the project, and there can be no assurance that we can obtain and maintain the necessary regulatory approvals and permits to complete the CP2 Project on the anticipated schedule. Accordingly, the actual project costs for the CP2 Project may be materially higher than this estimate. Moreover, the anticipated costs to achieve completion of the CP2 Project have increased in the past, and may increase further in the future, potentially materially, compared to our current estimates as a result of many factors, including delays in construction or commissioning of the project or the execution of any repair or warranty work and change orders under or amendments to certain material construction contracts, including final terms of or amendments to any EPC contract for the CP2 Project, and/or other construction or supply contracts resulting from the occurrence of certain specified events that may give the applicable contractor or supplier the right to cause us to enter into change orders or resulting from changes with which we otherwise agree. See “Risk Factors—Risks Relating to Our Projects and Other Assets—Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.”

Subject to regulatory approvals and market conditions, we are currently targeting final investment decision for Phase 1 of the CP2 Project in mid-2025 and for Phase 2 of the CP2 Project in mid-2026.

Commissioning LNG Sales

The CP2 Project is designed to utilize a similar project configuration and development approach as the Calcasieu Project and the Plaquemines Project. In contrast to traditional LNG facilities that are constructed by a single EPC contractor and include substantially fewer, larger-size liquefaction trains, our project design and configuration utilizes pioneering, mid-scale, factory-made liquefaction trains and other discrete systems and equipment, which require an extended commissioning period. Given this longer and gradual commissioning period, which starts with testing individual components and eventually extends to encompass testing and tuning our entire fully-integrated facilities, we expect to produce a substantial number of commissioning cargos. This production occurs during the period in which additional components of the relevant phase are brought into operation, completed and tested (including, if necessary, performing completion and rectification work to address unexpected performance deficiencies), to ensure the project is completed and achieves the performance levels necessary for stable, reliable long-term operations to supply LNG under the project’s post-COD SPAs. Based on the current engineering, procurement and pre-FID investments that we have made to advance the CP2 Project, we believe that the CP2 Project has the potential to produce LNG and load its first commissioning cargos earlier in the construction timeline and in greater quantities than our prior projects, based on the continual construction optimization techniques we have gained from installing and commissioning our numerous mid-scale liquefaction trains at the Calcasieu Project and the Plaquemines Project.

 

198


Table of Contents

Post-COD Contracts and Excess LNG Sales

As of September 30, 2024, we have entered into eight 20-year take-or-pay, post-COD SPAs in connection with the CP2 Project, or the CP2 Foundation SPAs, on an FOB basis.

These SPAs, as summarized below, all relate to Phase 1 of the CP2 Project and equate to 9.25 mtpa of LNG, which is approximately 64% of the expected nameplate capacity for Phase 1 of 14.4 mtpa. The majority of these offtakers have investment grade credit ratings and are among the industry’s strongest financial credits and include supermajors and nation state sponsored enterprises.

 

LOGO

The obligation to make LNG available under these SPAs commences from the occurrence of COD. All of these SPAs are structured for delivery on an FOB basis. The pricing structure and contractual obligations in the CP2 Foundation SPAs are substantially similar to the Calcasieu Foundation SPAs and the Plaquemines Foundation SPAs. See “—Calcasieu Project” for further information. Similar to the Calcasieu Foundation SPAs, the CP2 Foundation SPAs include termination rights in favor of the customer and us if certain conditions precedent are not satisfied by us or waived by the customer by a certain date including that we receive all LNG export authorizations by that date. Such dates certain have passed in two of the CP2 Foundation SPAs and are upcoming in March 2025 in the remaining CP2 Foundation SPAs. As a result, we or some of our customers under the CP2 Foundation SPAs may decide to terminate their SPAs if such future deadlines pass. See ”Risk Factors—Risks Relating to Our Business—Our customers or we may terminate our SPAs if certain conditions are not met or for other reasons.” We are negotiating an extension with those CP2 Foundation SPA customers whose current deadlines have passed and not yet been extended. In addition, our customers also have other limited termination rights if, among other things, COD for Phase 1 does not occur by a date that is approximately 60 months from the satisfaction of such conditions precedent, as may be extended in certain circumstances (including, among other things, in connection with a force majeure event).

We expect that any excess LNG produced by the CP2 Project above the nameplate capacity of 14.4 mtpa for Phase 1 or above the nameplate capacity of 5.6 mtpa for Phase 2 will be sold to VG Commodities under an Intercompany Excess Capacity SPA (one per phase) to be entered into for the relevant phase. LNG sold under such Intercompany Excess Capacity SPAs can, to the extent not previously committed to third parties, be resold to third party customers at our discretion under short-, medium- or long-term contracts, providing the flexibility to optimize pricing and capture additional revenue on an ongoing basis after COD for each of Phase 1 and Phase 2.

 

199


Table of Contents

CP3 Project

 

 

CP3 Project    Phase 1    Phase 2

Project location:

Site

   Approximately 840 acres in Cameron Parish, Louisiana

Property rights

   Ground lease for up to 70 years in total

Deep-water frontage

   Approximately 1 mile

Anticipated project design(1):

Expected nameplate capacity

   30.0 mtpa (phase and plant configuration remains to be determined)

Expected peak production capacity

   Up to 42.0 mtpa

Anticipated project timeline(1):

         

Targeted final investment decision / financial closing

  

Mid-2027

   Mid-2028

Targeted COD

   Mid-2032    Mid-2031

 

(1)

Anticipated based on capacity, scale, location and infrastructure, and may change based on design considerations, regulatory review process, engagement with contractors, and other factors. As of the date of this prospectus, no FERC and no DOE filings have been made and the necessary approvals for the CP3 Project have not been obtained. Accordingly, this is a target only, based on, among other things, anticipated timeframes for the receipt of the required DOE and FERC approvals. See “—Governmental Regulation” and “Risk Factors—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

Project Description

Our fourth project, the CP3 Project, is in the development stage and is designed as a natural gas liquefaction and export facility to be built in two distinct phases, with an expected nameplate capacity of 30.0 mtpa and an expected peak production capacity of 42.0 mtpa. We plan to locate the CP3 Project nearby the Calcasieu Project and the CP2 Project on approximately 840 acres of land in Cameron Parish, with approximately 1.0 mile of deep-water frontage on the Calcasieu Ship Channel.

Project Site Real Estate

In 2023, we entered into a 30-year lease (with extension rights) covering approximately 840 acres of land on which the CP3 Project will be located on or adjacent to. This lease may be extended at our option for up to four additional 10-year terms, up to 70 years in the aggregate.

Project Development

As of September 30, 2024, we have completed significant engineering studies and simulations, including certain marine berth simulations, in support of the project.

Although we have completed our initial consultation with FERC in December 2024, we have not initiated the pre-filing process for the CP3 Project with FERC or entered into definitive agreements with an EPC contractor or other key advisors and contractors necessary for the project’s development and construction. However, we have ample capacity under the Baker Hughes Master Agreement to contract for the potential supply of liquefaction trains and power island systems, which we expect to utilize for the CP3 Project. We expect that the construction, commissioning and operational start-up of the liquefaction plant will be substantially similar to our other projects.

 

200


Table of Contents

We currently estimate that the total project costs for the CP3 Project will range between approximately $44 billion and $45 billion, including EPC contractor profit and contingency, owners’ costs and financing costs, substantially all of which has yet to be funded. Our estimated total project cost is based upon our project cost experiences with the Calcasieu Project and the Plaquemines Project and reflects the current inflationary environment and that the CP3 Project’s pipelines are expected to be longer than the pipelines for the Calcasieu Project and the Plaquemines Project. However, we have not yet entered into an EPC contract or other key contracts for the development and construction of the CP3 Project. As a result, there can be no assurance that we will be able to enter into such contracts on similar terms to those for our initial projects. We have not yet prepared or submitted applications for key project permits or approvals. In addition, certain regulatory approvals and permits must be obtained on a timely basis in order to construct and operate the project, and there can be no assurance that we can obtain and maintain the necessary regulatory approvals and permits to complete the CP3 Project on the anticipated schedule. Accordingly, the actual project costs for the CP3 Project may be materially higher than this estimate. See “Risk Factors—Risks Relating to Our Projects and Other Assets—Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.”

Subject to regulatory approvals and market conditions, we are currently targeting final investment decision for Phase 1 of the CP3 Project in mid-2027 and Phase 2 of the CP3 Project in mid-2028.

Potential LNG Sales

We expect that the CP3 Project will utilize a similar project configuration, development approach, and reliability testing process as our initial projects. In contrast to traditional LNG facilities that are constructed by a single EPC contractor and include substantially fewer, larger-size liquefaction trains, our project design and configuration utilizes pioneering, mid-scale, factory-made liquefaction trains and other discrete systems and equipment, which require an extended commissioning period. Given this longer and gradual commissioning period, which starts with testing individual components and eventually extends to encompass testing and tuning our entire fully-integrated facilities, we anticipate that we will produce a substantial number of commissioning cargos. This production occurs during the period in which additional components of the relevant phase are brought into operation, completed and tested (including, if necessary, performing completion and rectification work to address unexpected performance deficiencies), to ensure the project is completed and achieves the performance levels necessary for stable, reliable long-term operations to supply LNG under the various post-COD SPAs that we anticipate entering into. While we have not yet entered into any LNG SPAs for the CP3 Project, we aim to market and sell the nameplate capacity at the CP3 Project under a combination of long-term 20-year SPAs as well as and short- and medium-term contracts to optimize the average fixed facility charge across our SPAs. Any excess LNG produced by the CP3 Project above the nameplate capacity for Phase 1 or above the nameplate capacity for Phase 2 is expected to be sold to VG Commodities under an Intercompany Excess Capacity SPA to be entered into for the relevant phase. LNG sold under such Intercompany Excess Capacity SPAs can, to the extent not previously committed to third parties, be resold to third party customers at our discretion under short-, medium- or long-term contracts, providing the flexibility to optimize pricing and capture additional revenue on an ongoing basis after COD of Phase 1 and Phase 2.

 

201


Table of Contents

Delta Project

 

 

Delta Project    Phase 1    Phase 2

Project location:

Site

   Approximately 1,100 acres in Plaquemines Parish, Louisiana

Property rights

   Option to lease for up to 70 years

Deep-water frontage

   Approximately 0.6 miles

Anticipated project design(1):

Expected nameplate capacity

   24.4 mtpa (phase and plant configuration remains to be determined)

Expected peak production capacity

  

Up to 34.2 mtpa

Potential bolt-on expansion incremental capacity

  

Up to 7.8 mtpa(2)

Anticipated project timeline(1):

Pre-filing with FERC

  

April 2019

Targeted final investment decision / financial closing

  

Mid-2029

  

Mid-2030

Targeted COD

  

Mid-2033

  

Mid-2034

 

(1)

Anticipated based on capacity, scale, location and infrastructure, and may change based on design considerations, regulatory review process, engagement with contractors, and other factors. As of September 30, 2024, definitive FERC and DOE filings have not been made and the necessary approvals for the Delta Project have not been obtained. Accordingly, this is a target only, based on, among other things, anticipated timeframes for the receipt of the required DOE and FERC approvals. See “—Governmental Regulation” and “Risk Factors—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

(2)

Potential bolt-on expansion opportunity based on facility capacity, scale, location and infrastructure. Subject to regulatory approval, among other things, and may change based on design considerations, regulatory review process, engagement with contractors and other factors.

Project Description

Our fifth project, the Delta Project, is in the development stage and is designed as a natural gas liquefaction and export facility to be built in two distinct phases, with an expected nameplate capacity of 24.4 mtpa and an expected peak production capacity of 34.2 mtpa. We plan to locate the Delta Project adjacent to the Plaquemines Project on approximately 1,100 acres of land in Plaquemines Parish, with approximately 0.6 miles of deep-water frontage on the Mississippi River.

Project Site Real Estate

Under our option agreements with the landowner of the Plaquemines Project and Delta Project sites, we have lease option agreements to lease up to approximately 1,100 acres of land for the Delta Project under substantially similar terms as our existing lease for the Plaquemines Project.

Project Development

As of September 30, 2024, we have completed significant engineering studies and simulations, including certain marine berth simulations, in support of the project.

 

202


Table of Contents

While we initiated the pre-filing process for the Delta Project with FERC in April 2019, we have not commenced the formal FERC approval process. In addition, we have not yet entered into definitive agreements with an EPC contractor or other key advisors and contractors necessary for the project’s development and construction. However, we have ample capacity under the Baker Hughes Master Agreement to contract for the potential supply of liquefaction trains and power island systems, which we expect to utilize for the Delta Project. We expect that the construction, commissioning and operational start-up of the liquefaction plant will be substantially similar to our other projects.

We currently estimate that the total project costs for the Delta Project will range between approximately $37 billion and $38 billion, including EPC contractor profit and contingency, owners’ costs and financing costs, substantially all of which has yet to be funded. Our estimated total project cost is based upon our project cost experiences with the Calcasieu Project and the Plaquemines Project and reflects the current inflationary environment and that the Delta Project’s pipelines are expected to be materially longer than the pipelines for the Calcasieu Project and the Plaquemines Project. However, we have not yet entered into an EPC contract or other key contracts for the development and construction of the Delta Project. As a result, there can be no assurance that we will be able to enter into such contracts on similar terms to those for the Calcasieu Project, the Plaquemines Project, and/or Phase 1 of the CP2 Project, as applicable. In addition, certain regulatory approvals and permits must be obtained on a timely basis in order to construct and operate the project, and there can be no assurance that we can obtain and maintain the necessary regulatory approvals and permits to complete the Delta Project on the anticipated schedule. Accordingly, the actual project costs for the Delta Project may be materially higher than this estimate. See “Risk Factors—Risks Relating to Our Projects and Other Assets—Our estimated costs for our projects have been, and continue to be, subject to change due to various factors.”

Subject to regulatory approvals and market conditions, we are currently targeting final investment decision for Phase 1 of the Delta Project in mid-2029 and Phase 2 of the Delta Project in mid-2030.

Potential LNG Sales

We expect that the Delta Project will utilize a similar project configuration, development approach, and reliability testing process as our initial projects. In contrast to traditional LNG facilities that are constructed by a single EPC contractor and include substantially fewer, larger-size liquefaction trains, our project design and configuration utilizes pioneering, mid-scale, factory-made liquefaction trains and other discrete systems and equipment, which require an extended commissioning period. Given this longer and gradual commissioning period, which starts with testing individual components and eventually extends to encompass testing and tuning our entire fully-integrated facilities, we anticipate that we will produce a substantial number of commissioning cargos. This production occurs during the period in which additional components of the relevant phase are brought into operation, completed and tested (including, if necessary, performing completion and rectification work to address unexpected performance deficiencies), to ensure the project is completed and achieves the performance levels necessary for stable, reliable long-term operations to supply LNG under the various post-COD SPAs that we anticipate entering into. While we have not yet entered into any LNG SPAs for the Delta Project, we aim to market and sell the nameplate capacity at the Delta Project under a combination of long-term 20-year SPAs as well as and short- and medium-term contracts to optimize the average fixed facility charge across our SPAs. Any excess LNG produced by the Delta Project above the nameplate capacity for Phase 1 or above the nameplate capacity for Phase 2 is expected to be sold to VG Commodities under an Intercompany Excess Capacity SPA to be entered into for the relevant phase. LNG sold under such Intercompany Excess Capacity SPAs can, to the extent not previously committed to third parties, be resold to third party customers at our discretion under short-, medium- or long-term contracts, providing the flexibility to optimize pricing and capture additional revenue on an ongoing basis after COD of Phase 1 and Phase 2.

 

203


Table of Contents

Key, Complementary Assets

Natural Gas Supply and Transportation

Natural Gas Supply Portfolio Approach

To the extent we produce LNG for export pursuant to our existing SPAs, we are responsible for procuring natural gas and transporting it to the relevant facility for liquefaction. We have entered into a portfolio of natural gas supply agreements with domestic natural gas suppliers to supply feed gas to the Calcasieu Project and the Plaquemines Project, which we continue to expand to suit the needs of our projects. We also anticipate entering into long-term natural gas supply arrangements with large upstream gas producers that will integrate their gathering and processing facilities into our planned pipeline network and deliver natural gas to our project facilities for liquefaction. Assuming we are able to operate our projects at their expected peak production capacity, we anticipate that we will require approximately 1.9 Bcf/d of natural gas for the Calcasieu Project, 4.2 Bcf/d of natural gas for the Plaquemines Project, 4.3 Bcf/d of natural gas for the CP2 Project, 6.5 Bcf/d of natural gas for the CP3 Project, and 5.3 Bcf/d of natural gas for the Delta Project. We have constructed lateral pipelines to connect the Calcasieu Project and the Plaquemines Project to the ANR Pipeline Company, Texas Eastern Transmission LP, and Sabine Pipe Line systems, and the Columbia Gulf, Texas Eastern Transmission LP, and Tennessee Gas Pipeline systems, respectively. Similarly, we intend to construct pipelines to connect our other current projects and any other future projects we may seek to develop to major interstate and intrastate pipelines. In addition, as described below, we aim to own other natural gas pipelines that support or, when constructed, will support our production facilities. Such connections allow us to access highly liquid upstream supplies.

Under our long-term supply agreements, we seek to contract natural gas for basis discounts to the Henry Hub index which can help secure natural gas availability and reduce our long-term exposure to volatility in natural gas prices. Our projects are near several major interstate and intrastate pipelines and are close to one of the more robust and liquid gas trading hubs (i.e., Henry Hub) for pipeline quality natural gas in the United States. We believe that these project locations provide numerous low-cost natural gas supply options for our projects, including onshore and offshore resource plays and natural gas storage facilities, resulting in greater reliability and optionality for sourcing our natural gas supply.

Natural Gas Transportation: Contracted Pipeline Capacity and Pipeline Development

We are developing, permitting, constructing and securing transport capacity agreements for midstream natural gas pipeline infrastructure that is intended to support our liquefaction growth strategy and help ensure stable and cost-effective access to the natural gas that fuels our LNG exports.

We have entered into a number of transport capacity agreements and related service agreements with interstate pipeline companies to provide the natural gas transportation to the Calcasieu Project and the Plaquemines Project. The Calcasieu Project and the Plaquemines Project were each sited and sized to facilitate ready connectivity to existing natural gas pipeline network infrastructure with the construction of short-run lateral pipelines. These lateral pipelines (the TransCameron Pipeline and the Gator Express Pipeline), and the major, third-party interstate pipelines to which they are connected, provide natural gas supply primarily from two major shale formations – the Haynesville and the Marcellus/Utica plays – though there is access to other US shale basins though interconnects into the third-party interstate pipelines.

Our existing gas transportation agreements for the Calcasieu Project and the Plaquemines Project are long-term commitments of approximately 20 years from the commencement of service, with extension rights following the initial term.

We have acquired all of the land rights required to construct and operate the TransCameron Pipeline and the Gator Express Pipeline for the Calcasieu Project and the Plaquemines Project. We are also currently in the

 

204


Table of Contents

process of securing servitudes, rights of way, crossing agreements, and any permits necessary for us to construct the interstate and intrastate pipelines discussed below, lateral pipelines and related infrastructure required to interconnect the CP2 Project, the CP3 Project and the Delta Project with existing interstate and intrastate natural gas pipeline system.

The TransCameron Pipeline is the lateral pipeline that delivers natural gas to the Calcasieu Project. The Calcasieu Project holds firm transport capacity of 2.35 TBtu/day on several pipeline systems delivering into its TransCameron supply header system including ANR Pipeline Company, Texas Eastern Transmission LP, and Sabine Pipe Line systems. Additionally, the Calcasieu Project holds firm transport capacity of 700,000 Dth/d, reducing to 625,000 Dth/d in April 2025, on the TC Louisiana Intrastate Pipeline, providing the ability to transport Haynesville production into ANR Pipeline for both supply security and beneficial pricing. The TransCameron Pipeline achieved substantial completion in April 2021 and final completion in July 2021 and has been commissioned and placed in service by FERC.

The Gator Express Pipeline is the lateral pipeline that delivers natural gas to the Plaquemines Project. The Plaquemines Project holds firm transport capacity of 4.225 TBtu/day on several pipeline systems delivering into its Gator Express supply header system including Columbia Gulf, Texas Eastern Transmission LP, and Tennessee Gas Pipeline systems. Additionally, the Plaquemines Project holds firm transport capacity of 575,000 Dth/d on the TC Louisiana Intrastate Pipeline, providing the ability to transport Haynesville production into Columbia Gulf for both supply security and beneficial pricing. The Gator Express pipeline achieved mechanical completion in October 2023 and its laterals were placed in service in May 2024 and in December 2024.

The proposed CP Express Pipeline will consist of 85.4 miles of 48-inch-diameter natural gas pipeline in Jasper and Newton Counties, Texas and Calcasieu and Cameron Parishes, Louisiana, and a 6.0-mile-long, 24-inch-diameter lateral off that mainline in northwest Calcasieu Parish. For the CP Express Pipeline we have secured an agreement, subject to FID of the CP2 Project, for firm transport capacity on the TC Louisiana Intrastate Pipeline LLC (1.4 TBtu/day expanding to 1.9 TBtu/day) to transport Haynesville production into CP Express in Louisiana. In addition, subject to CP2 Project requirements, we expect CP Express will interconnect with additional upstream pipeline infrastructure that secures delivery of gas from additional production basins.

We are in the development and siting process to optimize the plans for the pipelines to support the CP3 Project and the Delta Project.

As we are expanding our development footprint with the CP2 Project, the CP3 Project and the Delta Project, these projects’ production capacities are anticipated to require natural gas volumes that will support the construction of longer interstate and intrastate pipelines that provide incremental access and delivery capability from the Permian, Haynesville, Western Haynesville, Eagle Ford and mid-continent shale formations.

We plan to construct significant pipeline infrastructure, both independently and in partnership with certain qualified third parties, sufficient to source the required natural gas for these projects from primarily the Permian, Haynesville and Western Haynesville shale plays.

For example, we have partnered with WhiteWater Midstream, LLC, a Texas-based pipeline developer and operator, and through our wholly-owned subsidiary Venture Global Midstream Holdings, LLC, have entered into a limited liability company agreement with WhiteWater Blackfin Holdings, LLC pursuant to which we hold 50% of the equity interests in Blackfin Pipeline Holdings, LLC. Under this agreement, we have committed to jointly develop, permit, site and indirectly own the 190 mile Blackfin pipeline project, which upon construction is expected to include a long-haul 48-inch intrastate pipeline designed to facilitate the transportation of Permian sourced gas from the Matterhorn Express pipeline to certain interconnecting pipelines, including the CP Express Pipeline. Under the limited liability company agreement, we have agreed to fund certain construction and development costs and seek to arrange a financing to support the Blackfin pipeline project. We have secured firm transport capacity on Matterhorn Express Pipeline, LLC (2.0 TBtu/day, expanding to 3.3 TBtu/day) that will feed

 

205


Table of Contents

into Blackfin pipeline. The requisite pipeline and compression equipment for the Blackfin pipeline has been procured under contracts with Borusen Berg Pipe and Solar Turbines, a subsidiary of Caterpillar, and construction commenced in October 2024. As of September 30, 2024, we acquired 191 miles of pipeline materials and secured 12 Solar Titan 250 compression turbine units to support the development and construction of the Blackfin pipeline.

We have also commenced early development activities for two additional long-haul pipeline projects to support our planned development projects. The first pipeline project is anticipated to be an approximately 291 mile, 48-inch intrastate pipeline in Louisiana that is designed to transport up to approximately 4.5 TBtu/day of natural gas from northeast Louisiana close to our projects located in Plaquemines parish. The second pipeline project is anticipated to be an approximately 644 mile, dual, 48-inch intrastate pipeline in Texas that is designed to transport up to approximately 6.5 TBtu/day of natural gas from the Permian Basin to Eastern Texas, which is proximate to our projects located in Cameron parish.

LNG Tanker Fleet

In order to vertically integrate our business and expand our customer base to premium markets that have limited or no LNG transportation resources, we have contracted to acquire and charter a fleet of at least eleven LNG takers to build out our shipping portfolio. We plan to utilize such LNG tankers, when delivered, to help us manage the considerable volume of potential commissioning cargos produced during facility commissioning, sell excess capacity on a delivered basis and service our single existing post-COD DPU SPA and any future SPAs where LNG is sold on a delivered basis.

As of September 30, 2024, we have entered into purchase contracts to acquire nine LNG tankers, which are being constructed by two of the premier shipbuilders in South Korea, with two LNG tankers having already been delivered. The remaining LNG tankers are under construction and are scheduled to be delivered on a rolling basis through 2026. As of September 30, 2024, an aggregate of approximately $1.2 billion remains payable under such purchase contracts through the final delivery of the LNG tankers, subject to certain adjustments set forth in the contracts. Each contract requires payment be made to the counterparty in a fixed number of installments, which are due upon satisfaction of certain milestones in the construction process (of which approximately $1.1 billion have been paid as of September 30, 2024), with the final payment due on the date of delivery of the applicable LNG tanker.

All nine of such newbuild LNG tankers will be primarily fueled by LNG and are designed with best-in-class environmental and efficiency technology. LNG tankers which run on LNG, such as ours, can reduce CO2 emissions by 20-30% compared to tankers that operate with heavy fuel oil. We plan to have our tankers equipped with engines that are designed to significantly reduce methane slip by approximately 66% or more, versus the standard engines used on legacy LNG carriers. Also, we believe our LNG tankers are far more energy efficient than what is typical, due to a hydrodynamic hull design, which is expected to reduce propulsion power by approximately 10%, and the implementation of an air lubrication system that is intended to reduce hull friction and propulsion power requirements by approximately 3%.

To supplement our LNG tanker acquisitions, we have entered into two short-term charters for additional LNG tankers to facilitate commissioning cargo sales, provide additional operational flexibility, and expand LNG marketing opportunities. Such chartered LNG tankers were delivered to us in August and September 2024. We anticipate that we may seek to enter into similar arrangements from time to time in the future, as needed.

We believe these LNG tankers will help optimize LNG marketing and sales activities, and thereby can help improve our profit margin and differentiate us from other LNG exporters in North America, many of which are not pursuing a strategy to obtain or contract for shipping capacity. Utilizing our fleet, we can also service customers that lack access to shipping capacity and are solely reliant on costly intermediaries for deliveries.

 

206


Table of Contents

LNG Regasification Capacity

We are pursuing opportunities to secure LNG regasification capacity in key import markets to support current and prospective customers and differentiate ourselves from other LNG exporters in North America. As part of this initiative, through our wholly-owned subsidiary, VG LNG Marketing, LLC, we have acquired firm regasification facility capacity at the largest LNG regasification terminal in Europe, Grain LNG in the United Kingdom. We have contracted to import 42 LNG cargos per year beginning, depending on the starting period, anytime between October 1, 2029 to April 1, 2030, to and until July 14, 2045, except for the period from April 1, 2030 to September 30, 2030, when only 13 LNG cargos can be imported. The annual capacity charge payment under this contract begins on COD of the usage of the terminal (currently scheduled for October 2029). This agreement may be terminated by the terminal operator in certain circumstances, including if we fail to maintain sufficient credit, which failure would result in an obligation to pay a termination penalty. Additionally, we have secured approximately 1 mtpa of LNG regasification capacity at the new Alexandroupolis LNG receiving terminal in Greece for five years, beginning in 2025. Our capacity will account for approximately 25% of the total terminal capacity at Alexandroupolis, or approximately 12 cargos annually.

We aim to use these contracted capacities to supply LNG and regasified natural gas directly into the European market to current and additional downstream customers. In addition, we regularly explore similar regasification capacity opportunities in other markets. We believe our regasification access will allow us to offer spot and term customers a differentiated service, ultimately positioning us to win market share.

Major Consultants and Contractors

In conjunction with our owner-led procurement and management approach, we are working with a team of consultants and contractors that assist us with the development, engineering, financing, construction, permitting, marketing and operation of our projects. The conventional approach utilized by developers for large-scale projects typically relies on a single, comprehensive EPC contract, delegating all or substantially all responsibility to construct a project to a single EPC contractor. In contrast, we decentralize the contracting approach for our projects and seek to manage key scopes of work directly with a collection of key contractors, each of which are experts in particular systems and equipment.

To implement our “design one, build many” approach, we have entered into the Baker Hughes Master Agreement that grants us the option to order significant quantities of liquefaction trains and power island systems for the projects that we develop. For each of our projects we also enter into certain design, procurement, and construction contracts for other key equipment and facilities such as the pre-treatment system, LNG storage tanks, perimeter wall, and marine facilities. As of September 30, 2024, we have entered into the Calcasieu EPC Contract, the Plaquemines EPC Contracts, the CP2 Phase 1 EPC Contract, the Baker Hughes Master Agreement, purchase orders with Baker Hughes, and several construction or procurement contracts for other key equipment and components of the Calcasieu Project, the Plaquemines Project and the CP2 Project. To the extent not yet in place, we aim to negotiate and to enter into agreements on similar terms to those for the Calcasieu Project and the Plaquemines Project for the construction of our development projects.

Baker Hughes

The Baker Hughes Master Agreement provides for the supply of substantial incremental nameplate liquefaction and power equipment well in excess of the expected 104.4 mtpa nameplate capacity of our current project portfolio. Subject to our compliance with the Baker Hughes Master Agreement, such incremental equipment can be utilized for our development projects and any bolt-on expansions or additional projects that we may seek to develop in the future. Under the Baker Hughes Master Agreement, Baker Hughes is required to supply such equipment at an agreed upon price and schedule with reserved manufacturing capacity.

Purchase orders under the Baker Hughes Master Agreement contain terms and conditions, scope of supply, delivery schedule and performance tests and performance guarantees. We are limited under this agreement from

 

207


Table of Contents

contracting with an alternate equipment supplier to Baker Hughes, even in the event our preference is to do so. All of the liquefaction purchase orders and power island system purchase orders for the Calcasieu Project, the Plaquemines Project, and the CP2 Project follow the terms and conditions specified in the applicable form purchase order included in the Baker Hughes Master Agreement.

Under the Baker Hughes Master Agreement and related purchase orders, Baker Hughes has committed to satisfy key performance, reliability and LNG quality guarantees for the liquefaction and, as applicable, power equipment it supplies. In particular, if the relevant equipment fails to pass specified performance tests, then Baker Hughes is required to perform all work necessary to cause those systems to successfully pass the performance tests at its own expense or pay liquidated damages under certain performance guarantees.

Baker Hughes has agreed to reserve dedicated manufacturing capacity for the required components for our projects, which is sufficient to cover our five existing and contemplated projects, as well as incremental capacity that can be utilized for bolt-on expansions or future projects. The obligation to reserve manufacturing capacity expires in a staggered manner if we do not execute definitive purchase orders for the applicable portions of these components by certain mutually agreed dates. We have already executed the necessary purchase orders for the Calcasieu Project, the Plaquemines Project, and the CP2 Project and, based on our anticipated project schedule and barring unforeseen delays, we currently expect that we will be in a position to deliver the purchase orders for the CP3 Project and the Delta Project to Baker Hughes by the applicable deadlines in the Baker Hughes Master Agreement, as those deadlines may be amended from time to time.

In addition to the reservation of manufacturing capacity, the Baker Hughes Master Agreement contains an agreed-upon price structure and schedule for the equipment that Baker Hughes is obligated to supply, except for certain alternative configurations of power island systems, in which case the agreed-upon price structure and schedule is adjusted. The Baker Hughes Master Agreement generally provides for various staggered delivery dates for the first delivery of components, subject to the determination of final technical details of the equipment supplied as well as the terms of their respective purchase orders. Furthermore, we and Baker Hughes have agreed upon the pricing framework for the various components required for our liquefaction systems, which remain subject to adjustments based on changes to the scope of equipment and/or operations, negotiations in good faith and/or other modifications pursuant to the terms and conditions of the purchase orders when delivered.

The Baker Hughes Master Agreement includes pre-negotiated forms of purchase orders for the supply of liquefaction systems and power plants. Each purchase order is required to contain terms and conditions, scope of supply, delivery schedule and performance tests and performance guarantees. Unless and until we execute purchase orders for the equipment and issue notices to proceed under those orders, neither we nor Baker Hughes has any binding obligations with respect to the supply of any equipment under the Baker Hughes Master Agreement. Once we execute any purchase order with Baker Hughes for the supply of equipment, we may terminate that purchase order at our discretion. However, if we do terminate any purchase order, we are required to pay a termination fee to Baker Hughes, which is intended to reflect the out-of-pocket costs that Baker Hughes expects to incur in connection with such termination that it is not able to mitigate. As a result, if termination occurs in the mid-to-late stage of Baker Hughes’ performance of a purchase order, the termination fee payable in respect of that purchase order would approach, but would not exceed, the contract price for that purchase order.

In addition, we have the right under the Baker Hughes Master Agreement to require Baker Hughes to enter into a long-term service agreement on specified terms with respect to long-term maintenance, repair, and servicing of the liquefaction, power, and booster compressor equipment it supplies. We exercised such right for the Calcasieu Project and signed such a long-term service agreement with Baker Hughes in December 2022. Moreover, pursuant to the form long-term service agreement and the Calcasieu Project’s long-term service agreement, Baker Hughes is required to provide a long-term availability guarantee whereby Baker Hughes guarantees that the equipment it supplies will reach a minimum annual operating availability. If the equipment Baker Hughes supplies is unable to reach the specified operating availability, liquidated damages will be payable

 

208


Table of Contents

by Baker Hughes. To the extent the liquefaction system reaches an operating availability in excess of a certain level, we would be obligated under any such long-term service agreement to pay Baker Hughes a bonus based upon the amount of such excess. Both Baker Hughes’s and our respective obligations under this long-term service agreement would be subject to certain agreed limitations on liability.

EPC Contracts

Our project companies directly negotiate and contract with, as well as oversee and manage, our equipment vendors for the delivery of the majority of the critical facilities and modules related to LNG production. While we also typically engage an EPC contractor, such EPC contractors increasingly have a limited work scope, far less than for traditional facilities.

We constructed the Calcasieu Project pursuant to an EPC contract and have certified that it was performed in February 2023, subject to customary warranty obligations. In addition, we have entered into EPC contracts for both phases of the Plaquemines Project and for Phase 1 of the CP2 Project that require that the applicable contractor integrate such equipment and facilities and guarantee the full operation of the LNG export facilities. The services under the EPC contracts include contributing to the (i) design of balance of the plant and all interconnections including piping, utilities and associated infrastructure, (ii) procurement of all items not covered by our other construction and supply agreements, (iii) scheduling and coordination of the work and services performed by certain subcontractors and other contractors, (iv) site preparation, (v) installation and connection of all equipment supplied by our equipment suppliers, (vi) construction of the power plant forming part of the project, (vii) compliance with the contractor’s warranty obligations and all applicable laws, codes and standards, and (viii) provision of project controls and construction performance indicators and invoice reconciliation.

Under each such contract that we have entered into for our projects, the EPC contractor has an uncapped make-good obligation to deliver a facility capable of passing certain performance tests. Each contractor is also required to pay us liquidated damages, subject to a specified cap and sub-limits for certain milestones, for any construction and/or performance testing delay. The aggregate amount of liquidated damages that would be payable under this arrangement with respect to each of these projects, in addition to the liquidated damages that would be payable under certain performance guarantees under the applicable liquefaction and power equipment purchase orders entered into pursuant to the Baker Hughes Master Agreement, are expected to be up to 10% of the aggregate construction cost for each project.

Further, under each such contract, the EPC contractor warrants that (i) it will perform the work under the EPC contract in full compliance with such contract, (ii) the materials and the work will be designed, manufactured, engineered, constructed, completed, pre-commissioned, commissioned, tested and delivered in a workmanlike manner and in accordance with each respective EPC contract, our standards, all permits and approvals of government authorities, applicable codes and standards and all applicable laws, (iii) the work will conform to the specifications and descriptions in its EPC contract, will be new, complete, and of suitable grade for the intended function and use, will be free from defects in design, material and workmanship, and will meet the requirements set forth in its EPC contract, (iv) the materials will be composed and made of only proven technology, of a type in commercial operation at the effective date of its EPC contract, (v) if a serial defect (two or more of the same components experience a defect of an identical or nearly identical nature) occurs as to its work done under the EPC contract prior to the expiration of each respective warranty period, it will redesign, repair or replace any materials as necessary and extend each respective warranty period for that portion of the work that is redesigned, repaired or replaced for an additional 12 months, and (vi) during the warranty period, it will perform tests, inspections or other diagnostic services requested by us and correct any non-conforming work discovered.

For Phase 2 of the CP2 Project and our other development projects, we aim to negotiate and enter into EPC contracts on similar terms as described above. However, as compared to the Calcasieu Project, the Plaquemines Project and Phase 1 of the CP2 Project, we aim to manage additional scopes of work directly. Specifically, we anticipate that we will perform additional EPCM activities and deploy labor that we recruit to leverage lessons learned and the

 

209


Table of Contents

relationships fostered with construction and fabrication subcontractors while developing the Calcasieu Project and the Plaquemines Project, which we believe will help improve construction efficiency and reduce total costs for such projects. The EPC contracts we have used for the Calcasieu Project, the Plaquemines Project and Phase 1 of the CP2 Project are narrower in scope than the industry standard lump-sum-turnkey EPC agreements used by some of our U.S. Gulf Coast competitors. We expect that the EPC contracts that we use in the future will be even narrower.

We believe the narrowed scopes of our EPC contracts provide certain advantages compared to the standard lump-sum turnkey or “wrap” structure. We believe that, counterintuitively, these traditional lump sum, turn-key, “fixed price” forms of EPC construction can often result in significant delays and change order-driven cost overruns that we are better able to mitigate through our owner-led approach. In addition to incorporating our owner-furnished equipment, we believe our contracts afford us far greater control, execution flexibility, and oversight of the construction process. Where we see opportunities to accelerate procurement and construction or mitigate risk, we have been able to procure equipment and commodities on an accelerated timeline and secure experienced incremental contractors with significant labor resources to supplement EPC efforts and address construction timeline risks.

In addition, we have built an internal EPCM capability, securing a team of experienced leaders and professionals from the EPC industry, primarily with prior relevant experience constructing the Calcasieu Project and the Plaquemines Project facilities. We believe this organization augments the skills and capabilities of our partner EPC contractors and enables proactive leadership and engagement that speeds construction, manages supply chain and project controls, exercises budget adherence and reduces overall project risk. As described above, we anticipate that we will seek to leverage such internal EPCM capabilities to manage additional scopes of work directly for our development projects to reduce cost and accelerate schedule.

Below is a summary of the Plaquemines EPC Contracts and the CP2 Phase 1 EPC Contract.

Plaquemines EPC Contracts

The Plaquemines EPC Contracts are separate contracts for Phase 1 and Phase 2 of the Plaquemines Project under which KZJV is the EPC contractor and which reflects the terms described above.

Under the Plaquemines EPC Contracts, KZJV will be paid a reimbursable sum for its scope of work, where we will reimburse KZJV for all reimbursable costs incurred in connection with the relevant work (such as costs for materials, transportation and equipment), plus a margin to cover overhead costs and expenses as well as an agreed profit margin. However, all other costs will not be reimbursed and will be borne by KZJV. The estimated reimbursable sum represents the “target price” for each phase of the Plaquemines Project, which is reflected in our estimated total cost for the Plaquemines Project. The target price is subject to adjustment under certain limited conditions, including pursuant to change orders we could submit with respect to the scope of work to be performed by KZJV or the project schedule.

The Plaquemines EPC Contracts establish an agreed project schedule for the applicable phase, including substantial completion deadlines and final completion deadlines, based on the achievement of the contractual conditions regarding the commissioning and completion of the LNG production systems that comprise Phases 1 and 2 of the Plaquemines Project, which may only be adjusted by change orders as provided in the Plaquemines EPC Contracts. Each of the project schedule milestones requires that the work performed meets or exceeds requirements under the Plaquemines EPC Contracts and certain material project schedule milestones additionally require that the work performed passes performance tests. KZJV has significant milestone and schedule-driven bonus incentives under the Plaquemines EPC Contracts that are intended to promote schedule adherence and a completion mindset. If KZJV fails to successfully pass the performance tests by the applicable deadlines for these milestones for reasons not caused by us or our other contractors, KZJV is obligated to perform all work necessary to successfully pass such tests at its own expense. Additionally, if KZJV exceeds the target price by certain agreed amounts, we could reduce KZJV’s profit margin according to certain predetermined thresholds and if KZJV incurs delays in the project schedule beyond certain deadlines, KZJV could potentially owe us liquidated damages (subject to specified caps).

 

210


Table of Contents

Conversely, if KZJV’s reimbursable costs are below the applicable target price or if KZJV completes certain work ahead of the applicable target schedule, (i) KZJV will be entitled to a share in certain benefits of cost savings and (ii) KZJV will receive incentive payments for early completion of certain milestones.

CP2 Phase 1 EPC Contract

Worley is the contractor under the CP2 Phase 1 EPC Contract. The CP2 Phase 1 EPC Contract is comparable in scope and terms to the Plaquemines EPC Contracts, with certain adjustments to account for the CP2 Project’s schedule and minor configuration differences. The CP2 Phase 1 EPC Contract also includes substantial completion deadlines and final completion deadlines, with associated bonus incentives and exposure to liquidated damages depending on adherence to the project’s schedule.

Like the Plaquemines EPC Contracts, under the CP2 Phase 1 EPC Contract, Worley will be paid a reimbursable sum for its scope of work under similar terms to those included in the Plaquemines EPC Contracts. However, we anticipate that we will seek to manage additional scopes of work directly acting as EPCM, based on lessons learned and the relationships we have fostered with construction and fabrication subcontractors while developing the Calcasieu Project and the Plaquemines Project. The target price under the CP2 Phase 1 EPC Contract is subject to adjustment under certain limited conditions, including pursuant to change orders we could submit with respect to the scope of work to be performed by Worley or the project schedule.

Carbon Capture and Sequestration Initiative

In May 2021, we announced plans for carbon capture and sequestration, or CCS, facilities at or near the Calcasieu Project and Plaquemines Project sites that will be designed to compress CO2 emissions from these projects and subsequently inject it into subsurface saline aquifers near the project sites, where it would be permanently stored. We plan to implement or utilize such CCS facilities at our other projects as well, such as the CP2 Project, the CP3 Project and the Delta Project, which are located nearby the Calcasieu Project and Plaquemines Project. We have conducted extensive studies to confirm the feasibility of the CCS facilities, have leased approximately 27,000 acres of pore space with the State of Louisiana, and are in the process of completing the remaining applications for regulatory approval. We believe we are one of the first movers in the deployment of this technology at scale and are working closely with regulators to become among the earliest commercial scale implementers of CCS capabilities.

Job Creation and Commitment to Local Labor and Community Stewardship

We aspire to set the standard for our industry in achieving positive impacts for our local communities and on a national level.

In connection with the development of our projects, we provide substantial direct and indirect employment opportunities and have been a significant contributor to the domestic labor market with the jobs that we have created and supported. Taken together, we estimate that the Calcasieu Project and Plaquemines Project have been supported by over 300 subcontractors across the country. At peak, we estimate that we have supported the employment of up to 9,000 construction jobs to construct the Calcasieu Project and Plaquemines Project. We expect to directly hire approximately 700 permanent employees to operate and manage such projects and have already filled substantially all of these positions.

We strive to hire in-state and local workers where possible and over 90% of the current direct employees at the Calcasieu Project and Plaquemines Project are from Louisiana. We anticipate that the CP2 Project will support the employment of over 7,500 on-site construction jobs at its peak and we expect to hire over 400 workers in permanent operational positions.

Further, we engage with the communities near our project sites by providing full-time employment and educational opportunities that allow local residents to develop new technical skills and succeed in related careers.

 

211


Table of Contents

We primarily pursue this through our “Will to Skill” program and our apprenticeship program. In 2020, we established our educational “Will to Skill” program in partnership with local colleges to provide technical training certifications to residents of the communities near our projects. As of September 30, 2024, over 290 individuals have graduated in the aggregate from the 25 cohorts of the Will to Skill program that we have offered in the various communities located near our project sites. Will to Skill participants graduate with occupational and industrial certifications that include construction, electrical, welding, maritime, and trucking skills. Additionally, in October 2023, we established a new apprenticeship program to provide a 12-month training program to local residents near Lake Charles. Upon the successful completion of the program, individuals are eligible to transition to full time VG employees as field operators and maintenance technicians.

We are a major financial supporter of the local communities in which we operate and have undertaken a multitude of community development and engagement activities. In particular, over the lifecycle of the Calcasieu Project, Plaquemines Project, and CP2 Project, we expect Venture Global will pay more than $6 billion in total Parish property taxes. Regarding outreach and engagement, we have established community advisory groups in each of the parishes where our projects are located. Such community advisory groups include local business owners, community leaders, and residents to meet quarterly and discuss how we can best contribute to the success of the nearby population. We have also instituted certain advancement and donation campaigns to assist with emergency response efforts and community health and safety initiatives with local sheriff officers and fire departments. Also, in Cameron Parish, where the Calcasieu Project and CP2 Project are located, we have developed a public recreation complex and food bank to serve the community and provide additional employment opportunities.

Human Capital Resources

Our human capital is our most valuable asset, and we place a high premium on attracting, developing and retaining talented and high performing employees. As of September 30, 2024, we had over 1,400 full-time employees working on our engineering, project development, project financing, corporate finance, legal and LNG marketing teams. As we develop and construct our projects, we expect to create additional highly skilled engineering, construction, manufacturing and operating full-time and contractor jobs in Louisiana, Texas and Virginia. We offer our employees a wide array of company-paid benefits and performance incentives, which we believe are competitive relative to others in our industry. Our employees are not represented by a labor union or covered by a collective bargaining agreement. We believe our relationship with our employees to be good.

Health and Safety

At Venture Global, safe and reliable operations are at the core of everything we do. We are committed to providing a safe work environment across our businesses and strive towards best in class practices. We have built a dedicated Health, Safety, Security, and Environment, or HSSE, team that is accountable for the safe and responsible execution of our projects and reports to our Chief Operating Officer. At our project sites, our goal is to implement comprehensive safety programs that are appropriate for the hazards present at the various stages of construction and commissioning. This includes daily safety inspections, recurring safety trainings, and regular safety meetings. Our rigorous safety standards are continuously reviewed and updated to ensure they are fit for purpose within our workforce and we aim to meet the highest possible benchmarks. We believe that a strong safety culture leads to better safety performance, better operational performance, and higher staff morale. The data supports this and we are eminently proud of our aggregate 0.17 TRIR which, when compared to the industry average for 2023 of 1.9 according to the Bureau of Labor safety statistics, is among the best in our industry and stands as testament to our commitments.

Governmental Regulation

Our operations are subject to extensive federal, state, and local regulation. Applicable laws require us to consult with applicable federal and state agencies, obtain and maintain applicable permits and authorizations, and

 

212


Table of Contents

comply with various ongoing regulatory requirements. This regulatory burden increases the cost of constructing and operating our projects, and failure to comply with such laws could result in substantial penalties and/or loss of necessary authorizations. See “Risk Factors—Risk Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects” for more information.

Federal Energy Regulatory Commission (FERC)

The siting, construction, and operation of our natural gas liquefaction and export facilities are subject to FERC’s approval and ongoing regulation, as is the construction and operation of our natural gas pipelines.

Under section 3 of the Natural Gas Act, or the NGA, any person proposing to site, construct, or operate facilities (including LNG terminals) to be used for the export of natural gas from the United States to a foreign country must obtain authorization from FERC. FERC exercises comprehensive regulation of interstate natural gas pipelines, including requiring a certificate of public convenience and necessity under NGA section 7 to construct and operate such a pipeline, and requiring that the rates and terms of service for pipeline transportation service be just and reasonable under NGA sections 4 and 5.

In addition to the initial FERC process for each of our projects summarized below, we note that throughout the life of each project, our LNG and pipeline facilities will be subject to ongoing FERC regulation and reporting requirements (as well as those of various other federal, state and local regulatory agencies). FERC’s jurisdiction under the NGA and NGPA allows it to impose civil and criminal penalties for any violations of the NGA or NGPA, and any rules, regulations or orders of FERC up to approximately $1.55 million per day per violation, including any conduct that violates the NGA’s prohibition against market manipulation.

Calcasieu Project

On September 4, 2015, we filed an application with FERC for authorization to site, construct and operate the Calcasieu Project. On February 21, 2019, FERC authorized the Calcasieu Project, as well as the construction and operation of the TransCameron pipeline, subject to numerous conditions, or the Calcasieu FERC Order. No requests for rehearing (or appeal) of the Calcasieu FERC Order were filed.

Construction and commissioning of the Calcasieu Project is subject to ongoing oversight by FERC and the Calcasieu FERC Order imposes ongoing conditions with which we must comply. Since issuance of the Calcasieu FERC Order, we have submitted to FERC over 120 “implementation plan” filings demonstrating compliance with the Calcasieu FERC Order’s conditions and requesting notices to proceed with various scopes of work on the Calcasieu Project, as well as over 80 “commissioning” filings related to various facilities. On February 11, 2022, FERC authorized the export of our first LNG cargo, and we loaded our first commissioning cargo on March 1, 2022. Although we have completed most of the construction of Calcasieu Project, the commissioning phase remains ongoing. As described in detail above in the “—Overview—Our Projects” section, on March 28, 2023, we submitted to FERC an update regarding commissioning and certain reliability challenges and needed repairs and replacements, which have contributed to a delay in commercial operations. FERC authorized our plans for the HRSG remediation on October 12, 2023, and continues to oversee the remediation work. On October 26, 2023, FERC authorized placing the last of our liquefaction blocks in-service while other facilities remain in the commissioning process. We expect to commence commercial operations in late 2024. In February 2024, FERC performed a construction and commissioning inspection, which included a review of the HRSG repair work. FERC noted that the various rectification and remediation work remains ongoing and found that Venture Global “was approaching the diagnosis and remediation of the equipment performance in a careful, technically sound manner” to correctly identify the unexpected equipment performance issues and establish a permanent solution. In its inspection report, FERC also concluded that construction and commissioning activities observed during its inspection were in compliance with the designs and plans filed with and approved by FERC.

 

213


Table of Contents

In May, July, August and November 2024, FERC performed subsequent construction and commissioning inspections and each time reached the same conclusions, while noting that additional progress had been made since FERC’s prior inspection and that it will continue to monitor progress.

On March 31, 2021, we requested authorization from FERC to place the TransCameron pipeline in-service, explaining that the TransCameron pipeline is mechanically complete and ready to commence service. FERC granted that request on April 7, 2021. The TransCameron pipeline was placed in service by FERC on April 20, 2021.

On December 3, 2021, we submitted an application with FERC to amend the terms of our FERC authorizations for the Calcasieu Project to increase the permitted capacity under optimal conditions from 12.0 to 12.4 mtpa. This “uprate” in the regulatorily authorized production capacity is based on updated engineering and vendor data, and does not involve the construction of any new facilities nor any modification of the previously authorized facilities. FERC approved that amendment and increased the authorized export capacity to 12.4 mtpa, subject to certain conditions, in an order issued on September 22, 2023.

On February 15, 2024, we submitted to FERC a request for a one-year extension of time, if deemed necessary, to the in-service condition in the Calcasieu FERC Order. Various parties filed objections to the request for extension of time, while generally contending that it is not necessary. FERC issued an order on June 10, 2024 establishing a procedure for it to receive additional comments from intervenors with respect to the request, following which FERC will issue an order on our request for an extension of time. The intervenors have filed supplemental comments and we have responded to them. The extension request remains pending at FERC.

Plaquemines Project

On February 28, 2017, we filed an application with FERC for authorization to site, construct and operate the Plaquemines Project. On September 30, 2019, FERC authorized the Plaquemines Project, as well as the construction and operation of the Gator Express pipeline, subject to numerous conditions, or the Plaquemines FERC Order. No requests for rehearing (or appeal) of the Plaquemines FERC Order were filed.

Construction of the Plaquemines Project is subject to ongoing oversight by FERC and the Plaquemines FERC Order imposes ongoing conditions with which we must comply. Since issuance of the Plaquemines FERC Order, we have submitted to FERC, as part of a continuing process, more than 137 “implementation plan” filings demonstrating compliance with the Plaquemines FERC Order’s conditions and requesting notices to proceed with various scopes of work on the Plaquemines Project, as well as our initial “commissioning” filings. We are proceeding with construction as the work is authorized by FERC. Notably, in recent months FERC has authorized all the activities needed to commence liquefaction and our first exports, including introducing natural gas into Liquefaction Blocks 1 and 2. The construction of the related Gator Express pipeline is also subject to oversight by FERC; the pipeline achieved mechanical completion in October 2023. With the requisite FERC authorization, we placed the two Gator Express lateral pipelines in-service in May 2024 and December 2024.

On March 11, 2022, we submitted an application with FERC to amend the terms of our FERC authorization to increase the authorized permitted production capacity under optimal conditions from 24.0 to 27.2 mtpa. This “uprate” in the regulatorily authorized production capacity is based on updated engineering and vendor data, and does not involve the construction of any new facilities nor any modification of the previously authorized facilities. FERC has not yet issued an order regarding this uprate amendment application, though it did issue the environmental assessment regarding it on January 6, 2023, concluding that approval of the amendment would not constitute a federal action significantly affecting the quality of the human environment. On June 21, 2024, PHMSA issued its Letter of Determination and concluded that the uprate project and related design modifications comply with the applicable siting requirements. We expect FERC to approve the amendment now that PHMSA has completed its siting review.

 

214


Table of Contents

CP2 Project

On December 2, 2021, we filed an application with FERC for authorization to site, construct and operate the CP2 Project, seeking a permitted production capacity of 28.0 mtpa, as well as the related CP Express pipeline. On June 27, 2024, FERC authorized the CP2 Project, as well as the construction and operation of the CP Express pipeline, subject to numerous conditions, or the CP2 Project FERC Order. In July 2024, a group of opponents composed mostly of environmental groups filed a request for rehearing of the FERC authorization, raising a number of challenges to the FERC authorization. In a notice issued in August 2024, FERC denied rehearing by operation of law while providing for further consideration. Project opponents consisting of numerous environmentalist organizations and certain individuals filed petitions for review of FERC’s authorization order with the US Court of Appeals for the D.C. Circuit on September 4, 2024. FERC denied a motion for stay of its authorization order on October 1, 2024. The D.C. Circuit denied a similar request for stay filed by Project opponents on November 8, 2024, and established a briefing schedule through April 2025. On November 27, 2024, FERC issued an order on rehearing that generally rejected the arguments opposing the CP2 Project and noted that it remains confident in the authorization order, but decided to partially “set aside” its prior analysis of the cumulative air impacts of emissions of nitrogen dioxide (NO2) and particulate matter less than 2.5 micrometers (PM2.5) and to prepare a supplemental Environmental Impact Statement concerning that topic and to address it along with certain other air quality issues in a future order that FERC anticipates issuing no later than July 24, 2025. FERC also announced that, due to its initiation of supplemental environmental review, it will not issue authorizations to proceed with construction until the Commission issues a further merits order. In response to FERC’s order on rehearing, the D.C. Circuit on December 13, 2024, granted an unopposed motion by FERC to hold the appeal in abeyance. In addition to the supplemental environmental review and the appeal, construction of the CP2 Project will be subject to ongoing oversight by FERC in accordance with the terms and conditions of the CP2 Project FERC Order. While we have already begun to submit implementation plans for this purpose. FERC has not yet authorized any on-site construction as of the date of this prospectus. There can be no assurance as to the timing of the supplemental environmental review, FERC’s further merits order, or authorizations from FERC for any on-site construction, and as a result there can be no assurance as to when we will be able to commence on-site construction for the CP2 Project.

CP3 Project and Delta Project

We have not yet submitted a formal FERC application for the CP3 Project or the Delta Project. Such approvals are subject to a number of risks, and there can be no assurances as to when we will file the formal applications or when we will receive the approvals, if at all. For more information on these risks, see “Risk Factors—Risk Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

DOE Export Authorizations

Section 3 of the NGA requires any person seeking to import natural gas from, or export natural gas to, a foreign country to obtain authorization from the DOE. The DOE’s Office of Fossil Energy and Carbon Management, or DOE/FECM, reviews applications to import or export natural gas.

The NGA sets forth separate standards of review for exports to (1) countries with which the United States has a free trade agreement requiring national treatment for trade in natural gas, or FTA Nations, and (2) countries with which there is no such free trade agreement in effect, or Non-FTA Nations. Applications seeking authorization to export LNG to FTA Nations are deemed consistent with the public interest and must be granted without modification or delay. FTA Nations currently include Australia, Bahrain, Canada, Chile, Colombia, Dominican Republic, El Salvador, Guatemala, Honduras, Jordan, Mexico, Morocco, Nicaragua, Oman, Panama, Peru, Republic of Korea and Singapore. In contrast, Non-FTA Nations export applications are subject to a public interest review. DOE/FECM will grant the requested authorization unless it finds, after providing for a public comment period, that the proposed exports will be inconsistent with the public interest, and may approve an

 

215


Table of Contents

application in whole or in part, and with such modifications and upon such terms and conditions as it deems necessary or appropriate. DOE/FECM’s established practice is to act on long-term authorizations to export to Non-FTA Nations only after the FERC has authorized the siting, construction and operation of the associated LNG facilities.

In January 2024, the Biden administration announced a temporary pause on new authorizations of natural gas exports to non-FTA Nations while the DOE conducts studies to update its analyses regarding whether the exports are “not inconsistent with the public interest” to consider the latest available information regarding macro-economic impacts, domestic energy prices, potential greenhouse gas or climate or other environmental effects, and national security implications. On July 1, 2024, a Federal District Judge in Louisiana granted a motion for preliminary injunction by numerous states, holding the DOE pause appears to be unlawful and staying the pause in its entirety. The DOE has appealed that decision and has not acted on various pending export authorizations. The DOE did issue a non-FTA export authorization for one project on August 31, 2024 (NFE Altamira FLNG, a 2.8 mtpa project) but limited its term to 5-years, ruling that a more complete record is needed to evaluate a longer term. Attention to DOE’s approach to export authorizations resulted in legislative efforts intended to facilitate LNG exports. In July 2024, Senators Manchin and Barrasso, the Chairman and Ranking Member of the Senate Energy and Natural Resources Committee, respectively, released bipartisan legislation intended to strengthen American energy security by accelerating permitting processes that would, among other things, require DOE to approve or deny all pending and future applications to export LNG to non-FTA nations within 90 days after publication of the related final NEPA document.

On December 17, 2024, DOE publicly released a multi-volume study of its views of the potential effects of U.S. LNG exports on the domestic economy; U.S. households and consumers; communities that live near locations where natural gas is produced or exported; domestic and international energy security, including effects of U.S. trading partners; and the environment and climate. DOE stated that it intends to use this study to inform its public interest review of and future decisions regarding exports to non-FTA nations. The study is subject to a sixty-day public comment period and the finalization of the study and any application of it in future decision-making will be determined by the new presidential administration.

President-elect Trump made statements during his campaign opposing the DOE pause on export authorizations and also advocated for the prompt issuance of new authorizations. While the incoming Trump Administration is widely expected to support LNG exports, there can be no assurance as to its views of the recently released DOE study or its future policies, or the impact of those policies on our existing and future projects, including our related contracts. For more information on these risks, see “Risk Factors—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

Calcasieu Project

DOE/FECM approved our applications for exports from the Calcasieu Project to FTA Nations in May 2013 for 5 mtpa, in May 2014 for an additional 5 mtpa, and in February 2015 for an additional 2 mtpa. Thus, DOE/FECM granted our long-term export authorizations to FTA Nations in three separate orders, for a total volume of 620 Bcf/yr of natural gas (equivalent to 12 mtpa), and originally for a term of 25 years beginning the earlier of (i) the date of first export or (ii) seven or eight years (depending on the specific terms of each authorization) from the date of the authorization. DOE/FECM granted us long-term authorization for export to Non-FTA Nations on March 5, 2019. The Non-FTA export authorization also is for up to 620 Bcf/yr of natural gas (equivalent to 12 mtpa), and originally was for a term of 20 years from the date of first export, while providing that exports must commence no later than seven years from the date of the authorization. The authorized volumes to FTA Nations and Non-FTA Nations are not cumulative.

On August 12, 2020, we submitted to DOE/FECM an application requesting extension of the term in all the Calcasieu Project’s long-term export authorizations, pursuant to DOE/FECM’s final policy statement issued on

 

216


Table of Contents

July 29, 2020, entitled “Extending Natural Gas Export Authorizations to Non-Free Trade Agreement Countries Through the Year 2050.” On October 21, 2020, DOE/FECM granted that request, extending the term in each Calcasieu Project export authorization through December 31, 2050 (inclusive of any make-up period).

On December 18, 2020, DOE/FECM issued a blanket order, Order No. 4641, amending certain existing export authorizations, and amended the existing long-term authorizations for the Calcasieu Project to include short-term export authority, including to export commissioning volumes.

In accordance with the terms of our DOE export authorizations, we notified DOE of the export of our first export cargo from the Calcasieu Project on March 22, 2022. Subsequently, we have submitted monthly reports to DOE providing details regarding all our exports. We are also subject to various other reporting requirements regarding the Calcasieu Project under the terms of our export authorizations, including semi-annual status reports and the obligation to submit to DOE copies of all long-term LNG offtake and natural gas contracts. We have complied with these reporting requirements.

On December 3, 2021, we submitted an application with DOE/FECM to amend the terms of our FTA and non-FTA export authorizations for the Calcasieu Project to increase the authorized export capacity from 12.0 to 12.4 mtpa. As explained with regard to the related FERC application, this “uprate” in the regulatorily authorized production capacity is based on updated engineering and vendor data, and does not involve the construction of any new facilities nor any modification of the previously authorized facilities. DOE authorized the increased level of export to FTA Nations on April 22, 2022, but has not yet acted on the request to increase the authorized level of exports to Non-FTA Nations. Although President-elect Trump opposed the DOE pause on export authorizations and advocated prompt issuance of new authorizations in the course of his presidential campaign, we expect that most DOE long-term, non-FTA authorizations will be delayed at least until the new administration takes office and potentially thereafter. See “Risk Factors—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

Plaquemines Project

DOE/FECM approved on July 21, 2016, our application for exports from the Plaquemines Project to FTA Nations for 1,240 Bcf/yr of natural gas (equivalent to 24 mtpa), and originally for a term of 25 years beginning the earlier of (i) the date of first export or (ii) seven years from the date of the authorization. DOE/FECM granted us long-term authorization for export from the Plaquemines Project to Non-FTA Nations on October 16, 2019. The Non-FTA export authorization also is for up to 1,240 Bcf/yr of natural gas (equivalent to 24 mtpa), and originally was for a term of 20 years from the date of first export, while providing that exports must commence no later than seven years from the date of the authorization. The authorized volumes to FTA Nations and Non-FTA Nations are not cumulative.

On August 12, 2020, we submitted to DOE/FECM an application requesting extension of the term of the Plaquemines Project’s long-term export authorizations, pursuant to DOE/FECM’s final policy statement issued on July 29, 2020, entitled “Extending Natural Gas Export Authorizations to Non-Free Trade Agreement Countries Through the Year 2050.” On October 21, 2020, DOE/FECM granted that request, extending the term in each Plaquemines Project export authorization through December 31, 2050 (inclusive of any make-up period).

Just as for the Calcasieu Project, the blanket order described above also amended the existing long-term authorizations for the Plaquemines Project to include short-term export authority, including to export commissioning volumes.

We are subject to various reporting requirements regarding the Plaquemines Project under the terms of our export authorizations, including semi-annual status reports and the obligation to submit to DOE copies of all long-term LNG offtake and natural gas contracts. We have complied with these reporting requirements. Additional DOE reporting will be required once LNG exports commence.

On March 11, 2022, we submitted an application with DOE/FECM to amend the terms of our FTA and Non-FTA export authorizations for the Plaquemines Project to increase the authorized export capacity under

 

217


Table of Contents

optimal conditions from 24.0 to 27.2 mtpa. As explained with regard to the related FERC application, this “uprate” in the regulatorily authorized production capacity is based on updated engineering and vendor data, and does not involve the construction of any new facilities nor any modification of the previously authorized facilities. DOE authorized the increased level of export to FTA Nations on June 13, 2022, but has not yet acted on the request to increase the authorized level of exports to Non-FTA Nations, which is consistent with DOE practice of waiting to take action on the non-FTA portion of an application until after FERC has approved the corresponding project. Although President-elect Trump opposed the DOE pause on export authorizations and advocated prompt issuance of new authorizations in the course of his presidential campaign, we expect that most DOE long-term, non-FTA authorizations will be delayed at least until the new administration takes office and potentially thereafter. See “Risk Factors—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.”

In June 2024, the DOE authorized the Plaquemines Project to import LNG from various sources in total volumes up to the equivalent of 6 Bcf of natural gas, and authorized it to re-export the same quantity of previously imported LNG in July 2024. The Plaquemines Project utilized these blanket authorizations to cool-down its cryogenic facilities as part of the start-up of Phase 1 of the Plaquemines Project.

CP2 Project

DOE/FECM approved on April 22, 2022, our application for exports from the CP2 Project to FTA Nations for a 1,446 Bcf/yr of natural gas (equivalent to 28 mtpa), for a term extending through 2050. Our request for authorization for exports from the CP2 Project to Non-FTA Nations remains pending before DOE/FECM. Although President-elect Trump opposed the DOE pause on export authorizations and advocated prompt issuance of new authorizations in the course of his presidential campaign, we expect that most DOE long-term, non-FTA authorizations will be delayed at least until the new administration takes office and potentially thereafter. See “Risk Factors—Risks Relating to Regulation and Litigation—We may fail to receive the required approvals and permits from governmental and regulatory agencies for our projects.” DOE issued a statement on December 10, 2024, stating that it cannot complete its review of non-FTA export authorizations for projects still undergoing environmental review before other Federal agencies, specifically mentioning (among other projects) the FERC order on rehearing for the CP2 Project requiring supplemental environmental review. We are subject to various other reporting requirements regarding the CP2 Project under the terms of our FTA export authorization, including semi-annual status reports and the obligation to submit to DOE copies of all long-term LNG offtake and natural gas contracts. We have complied with these reporting requirements.

CP3 Project and Delta Project

We have not yet filed any application with DOE/FECM for the authorization of natural gas exports from the CP3 Project or the Delta Project. We anticipate submitting the export authorization application for the CP3 Project and the Delta Project at approximately the same time as our formal FERC applications for each project.

Department of Transportation Pipeline and Hazardous Materials Safety Administration

Our projects must comply with certain safety standards set by PHMSA. 49 C.F.R. Part 193, Federal Safety Standards for Liquefied Natural Gas Facilities, which establishes minimum federal safety standards for the siting, construction, operation, and maintenance of onshore LNG facilities and the siting of marine cargo transfer systems at waterfront LNG plants. These standards also incorporate by reference the National Fire Protection Association, Standard 59A, “Standard for the Production, Storage, and Handling of Liquefied Natural Gas.” Although PHMSA does not issue a permit in connection with LNG facilities, it participates as a cooperating agency during FERC’s review of a project to evaluate whether the proposed design meets DOT requirements. PHMSA issued a Letter of Determination, or LOD, regarding compliance with the applicable standards for each of the Calcasieu Project (including its “uprate” amendment) and the Plaquemines Project as part of the FERC process, before each project was authorized by FERC. PHMSA has also issued its LOD for the CP2 Project, as well as for the Plaquemines Project “uprate.” Once constructed and operational, each of our LNG facilities’ compliance with 49 C.F.R. Part 193 will be subject to DOT’s inspection and enforcement program.

 

218


Table of Contents

Other Governmental Permits, Approvals and Authorizations

The construction and operation of our projects is subject to additional federal and state permits, orders, approvals and consultations required by other federal and state agencies, including the DOE, U.S. Army Corps of Engineers, U.S. Department of Commerce, National Oceanic and Atmospheric Administration, National Marine Fisheries Services, Federal Aviation Administration, U.S. Fish and Wildlife Service, EPA, Louisiana Department of Environmental Quality and U.S. Department of Homeland Security. We currently have all material permits required for the Calcasieu Project’s and the Plaquemines Project’s respective current stage of construction and operations. Permitting for the CP2 Project remains ongoing, while permitting for the CP3 Project and the Delta Project is at an earlier stage.

Commodity Futures Trading Commission

We have entered into interest rate hedges, including interest rate swaps, in connection with the Plaquemines Credit Facility and the Calcasieu Pass Credit Facilities, and we may enter into additional interest rate hedges and other derivatives in the future. Pursuant to authority granted by the CEA, the CFTC exercises federal oversight and regulation of the derivatives market in the United States for most types of derivatives and entities, like us, that participate in that market.

Among other CFTC requirements, the CFTC’s swaps rules impose a range of regulatory requirements on parties transacting in swaps that, among other things: (i) provide for the registration and regulation of Swap Dealers and Major Swap Participants; (ii) impose clearing and trade execution requirements for certain swaps, subject to certain exceptions; (iii) establish swaps recordkeeping and reporting regimes; and (iv) implement the CFTC’s anti-manipulation, anti-fraud, and anti-disruptive trade practice authority.

“Swap Dealers” and “Major Swap Participants” must register with the CFTC and comply with heightened business conduct, reporting/recordkeeping, margin, and other requirements in connection with their swaps activities. Based on the level and nature of our swap activities (which are to hedge and mitigate commercial risk), we do not expect to fall within the CFTC’s definition of Swap Dealer or Major Swap Participant.

The CFTC has also made mandatory clearing determinations with respect to certain categories of swaps. The CFTC currently requires mandatory clearing of certain classes of interest rates and index credit default swaps, and may expand this requirement to additional categories of swaps in the future. Swaps subject to mandatory clearing must be submitted to a derivatives clearing organization, or DCO, for clearing, and in some cases, must be executed on an exchange or swap execution facility. Mandatory clearing and trade execution increase the transaction costs associated with swaps. However, the CEA provides an exception to the mandatory clearing and trade execution requirements for commercial end-users, or the end-user exception, provided the end-user is (i) not a “financial entity” as defined in the CEA; (ii) is using the swap to hedge or mitigate commercial risk; and (iii) complies with certain reporting and board approval requirements in connection with its election of the end-user exception, as applicable. We currently qualify for and rely on the end-user exception from the mandatory clearing and trade execution requirements in connection with our swaps activities; however, should we fail to qualify for the exception, we may be subject to DCO margin requirements, thereby increasing our swaps transaction costs.

Swaps that are not submitted to a DCO for clearing are subject to initial and variation margin requirements if the swap is between a Covered Swap Entity (i.e., a Swap Dealer or Major Swap Participant) and a “financial end user,” but these margin requirements do not apply to our uncleared swaps if we do not qualify as a financial end user.

In addition, CFTC position limits rules restrict the amounts of certain speculative futures contracts, as well as economically equivalent options, futures and swaps for or linked to certain physical commodities, including Henry Hub natural gas, that market participants may hold, subject to limited exemptions for certain bona fide

 

219


Table of Contents

hedging positions and other types of transactions. The application of these requirements affect the overall derivatives market, including the costs and availability of the types of swaps we use to hedge or mitigate our commercial risks.

As a commercial end-user, we are subject to only limited CFTC swaps requirements. However, the application of these requirements to other market participants may affect the overall swaps market, including the costs and availability of the types of swaps we use to hedge or mitigate our commercial risks. In addition, the CFTC’s swap requirements remain subject to changes from future rule amendments, interpretive guidance and no-action relief, and the ultimate effect on our business of any changes to the rules or interpretive guidance, or of any new rules in the future, remains uncertain.

Environmental Regulation

Our projects are subject to various federal, state, and local environmental statutes and regulations intended to ensure the protection of the environment. In certain cases, these environmental laws and regulations require us to obtain permits and authorizations and engage in agency consultations prior to construction and operation of a project. Many laws and regulations restrict or prohibit the types, quantities, and concentration of substances that can be released into the environment. Failure to comply with these laws and regulations may result in substantial civil and criminal fines and penalties. See “Risk Factors—Risks Relating to Regulation and Litigation—Existing and future environmental and similar laws and governmental regulations could result in increased compliance costs or additional operating and/or construction costs and restrictions” for more information.

Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA)

Certain aspects of our projects may be subject to the Comprehensive Environmental Response, Compensation, and Liability Act, or CERCLA, which provides for the investigation, cleanup, and restoration of natural resources from releases of hazardous substances (not including “petroleum”). We may be subject to liability under CERCLA as a result of contamination at properties currently or formerly owned, leased or operated by us or our predecessors or at third-party contaminated facilities to which we have sent waste for treatment or disposal. Liability under CERCLA can be imposed on a joint and several basis and without regard to fault or the legality of the conduct giving rise to contamination.

Clean Air Act (CAA)

Our projects are subject to the CAA and comparable state and local laws. Under the CAA, the EPA has the authority to control air pollution by issuing and enforcing regulations for entities that emit substances into the air. The EPA has promulgated regulations for major sources of air pollution and has delegated implementation of these regulations to state agencies, including the Louisiana Department of Environmental Quality and the Texas Commission on Environmental Quality. In addition to having obtained relevant air permits from the Louisiana Department of Environmental Quality prior to construction of the Calcasieu Project and the Plaquemines Project, we are subject to ongoing emissions standards, requirements, and reporting obligations. The EPA’s New Source Performance Standards regulate emission rates and impose emission limits and monitoring, reporting and record keeping requirements. The EPA has also issued a Mandatory Greenhouse Gas Reporting Rule, which requires petroleum and natural gas systems that emit 25,000 metric tons or more of CO2 a year to annually report GHG emissions to the EPA. Equipment subject to reporting under this rule includes LNG storage, regasification, and liquefaction equipment. We must also comply with Louisiana state air quality regulations and standards, codified in Louisiana Administrative Code Title 33, Part III. With respect to the CP2 Project, as a result of pipeline operations in Jasper County, Texas and Newton County, Texas, we will also be subject to the regulatory authority of the Texas Commission on Environmental Quality.

Coastal Zone Management Act (CZMA)

The Coastal Zone Management Act, or CZMA, is intended to ensure the effective management, beneficial use, protection, and development of the nation’s coastal zone. Under the CZMA, participating states are required

 

220


Table of Contents

to develop management programs demonstrating how they will meet their obligations and responsibilities in managing their coastal areas. The Louisiana Department of Natural Resources, which administers the CZMA for each of our projects, issued a coastal use permit and related mitigation plan for the Calcasieu Project and an exemption for the LNG terminal and a “no direct or significant impact” (NDSI) exemption for the marine facility for the Plaquemines Project. The CP2 Project received its CZMA authorization in March 2024.

Clean Water Act (CWA) and Rivers and Harbors Act

Our projects are subject to the CWA—which regulates discharges of pollutants into the waters of the United States—as well as analogous state and local laws. Under section 401 of the CWA, a federal agency may not issue a permit for any activity that may result in any discharge into the waters of the United States unless the state where the discharge would originate either issues a water quality certification verifying compliance with existing water quality requirements or waives the certification requirement or waives this requirement. Additionally, section 404 of the CWA regulates the discharge of dredged or fill material into waters of the United States, including wetlands. Each of the Calcasieu Project, Plaquemines Project, and CP2 Project has received a water quality certification from the Louisiana Department of Environmental Quality, Water Quality Division. The Calcasieu Project and the Plaquemines Project have received CWA section 404 permits from the U.S. Army Corps of Engineers, or USACE. For purposes of the Calcasieu Project and the Plaquemines Project, we also obtained permits from USACE under section 10 of the Rivers and Harbors Act, which is required for all construction activities in navigable waterways and permits from the Louisiana Department of Environmental Quality for the discharge of stormwater arising in connection with construction activities and industrial operations once construction is complete, and the discharge of wastewater generated during the operation of the facility.

Resource Conservation and Recovery Act (RCRA)

Under the Resource Conservation and Recovery Act, or RCRA, and comparable state hazardous waste laws, the EPA and authorized state agencies, including the Louisiana Department of Environmental Quality and the Texas Commission on Environmental Quality, regulate the generation, transportation, treatment, storage, and disposal of hazardous waste. If hazardous wastes are generated or stored in connection with any of our projects, we would be subject to the requirements of such laws.

Endangered Species Act, or ESA, Magnuson-Stevens Fishery Conservation and Management Act, or MSFCMA, and National Environmental Policy Act, or NEPA

Section 7 of the Endangered Species Act provides that any project authorized by any federal agency should not jeopardize the continued existence of any endangered species or threatened species, or result in the destruction or adverse modification of habitat of such species which is determined to be critical. The Magnuson-Stevens Fishery Conservation and Management Act, or MSFCMA, establishes procedures designed to identify, conserve, and enhance essential fish habitat for those species regulated under a federal fisheries management plan. During the FERC review process for each of our Projects, we engaged in consultation with the relevant federal agencies pursuant to the ESA and MSFCMA.

Such consultation was completed for the Calcasieu Project, the Plaquemines Project and the CP2 Project.

The CP3 Project and the Delta Project have not received their Section 7 clearance as of September 30, 2024.

The issuance of requisite permits and authorizations for our projects may be subject to environmental review under the National Environmental Protection Act, or NEPA. NEPA requires federal agencies to evaluate the environmental impact of major agency actions that may significantly affect the quality of the human environment, such as the granting of a permit or similar authorization for the development of certain projects. As part of NEPA review, federal agencies will prepare an environmental assessment that assesses the potential

 

221


Table of Contents

direct, indirect and cumulative impacts of a proposed project and, if necessary, will prepare a more detailed environmental impact statement that may be made available for public review and comment. In January 2023, the Council on Environmental Quality, or CEQ, issued interim guidance to assist agencies in analyzing GHG emissions and climate change effects under NEPA. Additionally, in September 2023, the White House directed agencies to consider the social cost of GHG emissions when conducting environmental reviews pursuant to NEPA, and in May 2024, CEQ published its final “Phase 2” NEPA regulations, which include specific direction to account for both climate change and environmental justice effects in NEPA reviews. The NEPA review process can lead to significant delays in approval of such projects and the issuance of the requisite permits. As a result of its NEPA review, a federal agency may decide to deny permits or other support for a project, or condition approvals on certain modifications or mitigation actions.

Seasonality

Seasonal weather can affect the need for our LNG sales. While we expect that a substantial amount of our LNG will be sold under long-term, post-COD SPAs, due to the commissioning activities at the Calcasieu Project, including the marketing, loading and shipping of our cargos of LNG, we have already begun experiencing, and we expect to experience for our other projects as we begin commissioning activities for such projects, the effects of market volatility and fluctuation in seasonal demand for LNG in our existing markets. Additionally, excess LNG produced by our projects above the nameplate capacity that is sold by VG Commodities or otherwise can, to the extent not previously committed to third parties, be resold to third party customers at our discretion under short-, medium- or long-term contracts, including on a forward spot basis, which would expose our revenues to such volatility and fluctuation in seasonal demand. Changes in temperature and weather may affect both power demand and power generation mix in the locations we service, including the portion of electricity provided through other sources of energy, such as hydroelectric, solar or wind, thus affecting the need for regasified LNG. These changes can increase or decrease demand for LNG and accordingly, fluctuations in revenue during quarters of high and low demand, respectively, could have a disproportionate effect on our results of operations, especially with regard to the LNG sold into the spot market. For more information on these risks, see “Risk Factors—Risks Relating to Our Business —Seasonal fluctuations will cause our business and results of operations to vary among quarters, which could adversely affect our business and results of operations, which could, in turn, negatively affect the price of our Class A common stock.”

Competition

The global LNG and natural gas markets are highly competitive. We compete with many participants across an integrated supply chain, including independent LNG producers, commodities marketing and trading firms, national energy companies, utility companies, and major multinational energy companies, primarily over supplies of natural gas and sales of our LNG. Historically, our competitors have developed LNG facilities at a scale and complexity that has gradually increased over time. We believe the costs associated with these other projects are further complicated by their bespoke nature, which limits the opportunity for process improvement and operational efficiency gains from one project to the next. In contrast, we utilize a repeatable configuration across the projects that we develop, which enables us to continually refine and optimize our LNG production operations. We believe our proprietary mid-scale, factory-built liquefaction train design, project execution excellence, access to well-priced and abundant, domestically sourced natural gas, simultaneous construction and integrated operations approach, with its associated commissioning cargos and proceeds, capital strength, leadership, and mission and values-led culture position Venture Global well to compete and thrive against this diverse competitive landscape.

Energy Supply & Demand and VG’s Competitive Advantage

LNG is a vital commodity needed across the world to provide reliable, low-cost, low-emission energy. We believe that our differentiated business strategy positions us to serve as a leading, low-cost supplier of this crucial fuel and play a major role in international energy markets.

 

222


Table of Contents

We believe our liquefaction technology, configuration, and owner-led approach allows us to bring substantial quantities of LNG to the market faster than competing LNG developers. We believe these capabilities, taken together with our pipeline developments, LNG tankers, and regasification assets, will allow us to supply energy to an increasing number of global customers to meet the world’s current and rapidly growing demand.

In the near- and medium-term, energy demand is projected to increase substantially. Such demand growth factors include existing macro-economic trends, such as the expansion of the world’s middle-class population, which will require additional access to energy-dependent consumer staples such as air conditioning, heating, and lighting. Additionally, new sources of significant energy consumption are emerging. For example, data center demand, driven by the burgeoning artificial intelligence industry, will accelerate this global demand story.

Given such robust and sustainable market dynamics, we believe that LNG has the potential to become an increasingly critical commodity to support such sources of demand, which require dispatchable and reliable, 24/7 baseload power. Our business model of developing, building, and delivering low-emission LNG is repeatable, portable – domestically and internationally – and well-positioned to address this growing need. We believe our model can be deployed on an industry-leading schedule to optimize our existing LNG projects with “inside-the-fence” expansions, as well as in new greenfield developments.

Simply put, we believe our scalable approach uniquely positions Venture Global to competitively serve the world’s growing energy demand.

Pricing Dynamics

We are subject to market-based price competition, reflecting supply and demand market pricing dynamics, with respect to revenue associated with any sales of our commissioning cargos and sales of LNG in excess of our nameplate capacity. Due to the commissioning activities at the Calcasieu Project, including the marketing, loading and shipping of our cargos of LNG, we have already begun experiencing competition with respect to LNG sales, including the effects of changes in supply and demand due to recent market volatility. The balance between the availability of LNG and the market demand for LNG significantly affects competition and the market price for our products. This dynamic is particularly acute for cargos sold on a forward spot or short-term contracted basis, such as any commissioning and excess capacity cargos.

Even after COD for our projects, we may continue to have a meaningful component of our production and sales subject to spot and short- or intermediate-term market dynamics. This may occur as a result of marketing excess capacity cargos through VG Commodities under excess capacity SPAs to the extent these cargos are not previously contracted, or as a result of marketing any portion of the nameplate capacity of our projects that is not contracted under post-COD SPAs at any time. LNG often supports base load power generation and other end uses among LNG offtakers. Accordingly, supplier geographic diversity is an important element of portfolio management for such offtakers. As offtake markets grow, we anticipate that producers based in the United States, such as Venture Global, will maintain or grow market share, with our competitive advantage supplemented by our logistics and delivery capabilities that are enabled by our fleet of LNG tankers. However, increases in the production of LNG by our competitors, could have a material adverse effect on the viability of any of our planned projects and on our ability to compete with them successfully.

Pricing and Contract Terms

Our longer-term post-COD SPAs for each of our projects are relatively more insulated from spot market price volatility than the sales of our commissioning cargos and any sales of LNG in excess of our nameplate capacity, given the contractual protections, price stability and predictability of both gas supply and LNG offtake. After any of our projects, or phase thereof, reaches its respective COD, the project is required to begin to deliver cargos to service its post-COD SPAs then in place for such project or phase. However, our projects may still be

 

223


Table of Contents

subject to market-based spot price competition if we need to replace any existing SPAs, whether due to natural expiration, customer default or otherwise.

The Calcasieu Project and the Plaquemines Project are not currently experiencing competition with respect to long-term LNG sales, given that each of their entire expected nameplate capacity has been contracted under post-COD SPAs. These projects would be subject to the risk of LNG price competition at times when we need to replace any existing post-COD SPAs, whether due to natural expiration, customer default or otherwise, or enter into new SPAs, as well as competition for sales of commissioning cargos. Our current development projects, any future projects we develop and any expansions of our projects will compete with other domestic and international suppliers on the basis of price per contracted volume of LNG with other LNG projects throughout the world, including other LNG projects being developed by us and other LNG projects in operation and under development.

The price of LNG captured by a project can be affected by, among other factors, global supply and demand, historical reputation, geopolitical stability, project location, interest rates, and contract flexibility. For example, increases in the production of LNG by our competitors, or decreases in their LNG prices, could have a material adverse effect on our ability to secure SPAs for our current development projects, any future projects we develop and any expansions of our projects.

Market Access and Participants

As a new market entrant, we compete against other companies with stronger brand recognition and more established relationships with customers. We believe that in a commodities market, lowest risk-adjusted liquefaction cost provides a key, sustainable competitive advantage, particularly for new market entrants. We believe our proprietary configuration, speed of construction and simultaneous construction and commissioning, with related commissioning cargo production, allows us to take a differentiated approach that seeks to reduce costs and compresses the timeline to produce and sell LNG after commencing full construction. Accordingly, we believe our projects are well positioned to compete globally. As demand for LNG, and more broadly, energy security grows, we believe that producers based in the United States, such as ourselves, may have the ability to maintain or grow market share.

In addition, we believe our planned fleet of LNG vessels, and their role in the energy supply chain, along with the regasification capacity we have contracted, enable us to compete against large institutional marketing and trading firms and market and optimize delivered cargos to customers that lack the ability to manage logistics for their own accounts.

Current and Potential Competitors

With respect to our projects, our current and potential competitors include, but are not limited to, (1) national energy companies, such as QatarEnergy, (2) major multinational energy companies, including BP, Chevron, ConocoPhillips, ExxonMobil, Shell and Total, (3) independent LNG producers, including Cheniere and Freeport LNG, (4) utility companies, such as Sempra, and (5) commodities marketing and trading firms, such as Glencore, Trafigura, and Vitol. Some of our competitors may have financial, engineering, marketing and other resources greater than we have, and some of them are fully integrated energy companies. Importantly, many of our competitors are also our customers with whom we have short-, intermediate-term and long-term contractual relationships.

For additional information about the risks to our business related to competition, see “Risk Factors—Risks Relating to the LNG Industry—Competition in the LNG industry is intense, and certain of our competitors may have greater financial, engineering, marketing and other resources than we have” and “Risk Factors—Risks Relating to the LNG Industry—We face competition based upon the international market price for LNG.”

 

224


Table of Contents

Insurance

We maintain a comprehensive insurance program to insure potential losses to Venture Global, the Calcasieu Project and the Plaquemines Project from physical loss or damage, including due to floods and named windstorms, as well as third-party liabilities, during construction and subsequent operation. We expect to establish a similar comprehensive insurance program for the CP2 Project, with initial environmental, third party liability and cargo policies in place, and our current development projects at the appropriate and prudent time. In addition, we expect to establish a comprehensive insurance program to insure against customary risks and losses for our LNG tankers and regasification terminal assets at the appropriate and prudent time and have already placed protection and indemnity coverage and hull and machinery insurance for our two, newbuild LNG tankers that were delivered in July 2024 and placed charterers’ liability insurance for our two chartered LNG tankers that were delivered in August and September 2024. We may not be able to maintain adequate insurance in the future at rates that are considered reasonable. See “Risk Factors—Risks Relating to Our Business—We will be unable to insure against all potential risks and may become subject to higher than expected insurance premiums. In addition, we retain certain risks as a result of insurance through our captive insurance.”

Construction All-Risk, or CAR, Insurance

We obtained Construction All-Risk insurance policies, or CAR policies, for the Calcasieu Project and the Plaquemines Project, consisting of a very large quota-share and layered property insurance programs written with specialist international insurers that have been placed solely for the construction of the projects. Such CAR insurance policies partially transition to Operating All-Risk (OAR) coverage as certain milestones are achieved and remain effective until the project achieves Facility Substantial Completion under the applicable EPC contracts (which occurred in late 2022 for the Calcasieu Project). Such insurance covers all construction or installation work including, coverage for mechanical and electrical breakdown as well as testing and commissioning required to complete the projects. The CAR policies also include Delay-in-Start-Up (DSU) coverage. This construction insurance has deductibles, waiting periods, sub limits, and aggregate limits that are normal and customary for these types of insurance policies. The CAR policy for the Calcasieu Project is no longer in effect given that the EPC work has been completed. The CAR policy for the Plaquemines Project has a combined limit for CAR and DSU of $2.2 billion with a standard deductible of $1 million per occurrence for property damage and a 60-day waiting period per occurrence for DSU. We expect to enter into similar CAR policies for our current development projects.

Third Party Liability, or TPL, Insurance

VGLNG has TPL insurance with a limit of $11 million. Third party liability risks are covered in the Terminal Operator’s Liability policy for the Calcasieu Project (described below). The Plaquemines Project has a TPL insurance policy which includes a limit of $200 million per occurrence and in the annual aggregate and that is subject to various sublimits, terms and conditions. The deductible amount is $1 million for each occurrence. Similarly, the CP2 Project has a TPL insurance policy which includes a limit of $200 million per occurrence and in the annual aggregate and that is subject to various sublimits, terms and conditions. The deductible amount is also $1 million for each occurrence. We expect to enter into a similar TPL policy for our current development projects.

Terminal Operator’s Liability and Operational All-Risk, or OAR, Property Insurance

Once our projects achieve certain completion milestones, their OAR policies come into effect and provide coverage for property and business interruption for such project. We intend to obtain insurance coverage that is in such form and in such amounts as are customary for project facilities of similar type and scale to our projects. For the Calcasieu Project and the Plaquemines Project, we maintain the following types of insurance as of September 30, 2024:

 

   

the Terminal Operator’s Liability Program, which is structured as a primary and layered excess liability insurance program, which provides cover for marine and land based third party liabilities. The policies

 

225


Table of Contents
 

have limits of $500 million per occurrence and in the annual aggregate and the deductible is $100,000 per occurrence;

 

   

the OAR Insurance, which is a large quota-share and layered property insurance program written with specialist international insurers. The Calcasieu Project cover has a combined limit of $2.4 billion for both physical damage and business interruption, the standard deductible for physical damage losses is $5 million per occurrence and the waiting period for business interruption losses is 60 days per occurrence. We intend to place a similar OAR program for the Plaquemines Project as it reaches the appropriate milestones.

Named Windstorm Insurance (NWS)

The Calcasieu Project and the Plaquemines Project each maintain a Named Windstorm Insurance Program, which is structured as a layered program with a limit of $250 million at each location. This is placed with VGLNG Insurance, LLC, or VGLNG Insurance, one of our subsidiaries. The Calcasieu Project has cover for physical damage and business interruption, while the Plaquemines Project has cover for CAR and DSU. The deductible for CAR/physical damage losses is $50 million per occurrence and the waiting period for DSU/business interruption losses is 60 days per occurrence. Losses in excess of $50 million but less than $100 million are retained solely by VGLNG Insurance. For losses in excess of $100 million but less than $300 million, VGLNG Insurance, LLC is reinsured 100% by reputable third-party insurers.

Total NWS-claims filed for the years ended December 31, 2023, 2022 and 2021 were $0, $0 and $0, respectively. VGLNG Insurance held $108 million in cash and cash equivalents at September 30, 2024 from premiums paid by the Calcasieu Project and the Plaquemines Project for the coverage described above. We expect that as we begin commercial operations at the Calcasieu Project, continue construction at the Plaquemines Project, and begin construction of our current development projects, we will continue to pay premiums to VGLNG Insurance to obtain adequate named windstorm risk-coverage for our projects. We anticipate that we will maintain similar policies for the CP2 Project, the CP3 Project and the Delta Project in the future.

Properties

In the aggregate, as of September 30, 2024, we owned, leased or had an option to lease or purchase nearly 6,000 acres of land on the United States Gulf Coast.

For the Calcasieu Project, we entered into ground leases with various landowners in Cameron Parish, Louisiana, for up to 70 years. These ground leases cover approximately 432 acres of land for an initial term of 30 years, with four 10-year extensions exercisable at our option. The Calcasieu Project site also benefits from eight separate material offloading sites that are situated on the east side of the Calcasieu Ship Channel, have access to the primary access road to the project site and are adjacent to the Calcasieu Project and the CP2 Project sites. They range from approximately three to ten acres, and we are using these offloading sites to offload equipment and building materials during construction. These offloading sites are held under ground leases by one of our subsidiaries and we have access to these sites under access license agreements with that subsidiary.

We also entered into a 30-year lease with the Plaquemines Port Harbor and Terminal District, covering the 630 acres of land on which the Plaquemines Project is located. This lease may be extended at our option for up to four additional 10-year terms, up to 70 years in the aggregate. We also have lease option agreements to lease up to an additional approximately 1,100 acres of adjacent land for the Delta Project under substantially similar terms as our existing lease for the Plaquemines Project.

We entered into various 30-year leases covering approximately 1,130 acres of land on which the CP2 Project will be located or adjacent to. We acquired fee ownership to approximately 27 acres of the project site in 2023.

 

226


Table of Contents

We also entered into a 30-year lease covering 840 acres of land for the CP3 Project. This lease may be extended at our option for up to four additional 10-year terms, up to 70 years in the aggregate.

We own the office space in Arlington, VA where our principal executive offices are located. In addition, we lease office space in Houston, TX; Singapore; London, England; and Tokyo, Japan. These office leases expire or become subject to renewal clauses at various dates.

Intellectual Property

We rely on a combination of intellectual property rights, including know-how, trade secrets, license agreements, confidentiality procedures, non-disclosure agreements, and employee non-disclosure to establish, maintain and protect our intellectual property and other proprietary rights. In particular, we license natural gas processing technology from third parties for each of our liquefaction facilities. In addition, under our agreements with Baker Hughes, we own certain know-how and trade secrets relating to aspects of the liquefaction systems, including the routing of the piping and valves within the liquefaction modules and optimization of other module designs, the sharing of supporting equipment between individual liquefaction trains, and the management of mixed refrigerant in the liquefaction process.

However, the efforts we have taken to protect our intellectual property rights may not be sufficient or effective. From time to time, legal action by us may be necessary to enforce or protect our intellectual property rights or to determine the validity and scope of the intellectual property rights of others, and we may also be required from time to time to defend against third-party claims of infringement, misappropriation or other violation. Additionally, although we take reasonable steps to safeguard our trade secrets, trade secrets can be difficult to protect, and others may independently discover our trade secrets and other confidential information. Failure to protect our intellectual property rights or other proprietary rights adequately could significantly harm our competitive position, business, financial condition and results of operations. See “Risk Factors—Risks Relating to Intellectual Property, Data Privacy and Cybersecurity—If we are unable to obtain, maintain, protect and enforce our intellectual property rights, our business may be adversely affected.”

Cybersecurity and Data Privacy

Our projects and any other natural gas liquefaction and export facilities we may decide to develop in the future include assets deemed by FERC to constitute critical energy infrastructure, the operation of which is dependent on our IT systems. These systems may thus be attractive targets for a cyber-attack. We maintain and update a cybersecurity program to safeguard our IT systems, including those that run and connect to IT systems that run our natural gas liquefaction and export facilities. We deploy a cybersecurity strategy that is designed to prevent cyber threats as well as recover from cybersecurity incidents with disaster recovery resources. The basis of design for our IT systems are standards that align with existing NERC CIP standards and comply with the most stringent NIST standards for data integrity. In addition to a group of network hygiene operating policies, we deploy network and perimeter firewall protections and cloud security packages. We also employ a multi-cloud backup strategy, with backups maintained on cloud platforms that facilitate restoration of plant and business capabilities. Finally, we also keep tape backups, as physical gold copies, that are sent periodically for offline tape storage in a secured storage facility. Regardless, a significant cyber incident involving our IT systems, or those of any of our third party vendors or contractors with which we do business, could negatively impact our operations. See “Risk Factors— Risks Relating to Intellectual Property, Data Privacy and Cybersecurity—Hostile cyber intrusions, or other issues with our information technology, could severely impair our operations, lead to the disclosure of confidential information, damage our reputation and otherwise have a material adverse effect on our business.”

We are also subject, or may become subject, to increasingly complex and changing laws, directives, industry standards, rules and regulations, as well as contractual obligations, related to data privacy and security in the United States and around the world that impose broad compliance obligations on the collection, transmission,

 

227


Table of Contents

dissemination, use, privacy, confidentiality, security, retention, availability, integrity and other processing of personal information. Any failure or perceived failure by us to comply with any laws, rules or regulations relating to data privacy and security could adversely affect our reputation, results of operations and financial condition. See “Risk Factors— Risks Relating to Intellectual Property, Data Privacy and Cybersecurity—Changes in laws, rules or regulations relating to data privacy and security, or any actual or perceived failure by us to comply with such laws, rules and regulations, or contractual or other obligations relating to data privacy and security, could adversely impact our business.”

Legal Proceedings

We are involved, and in the future may become involved, in various claims, lawsuits, and other proceedings incidental to the ordinary course of our business from time to time. For example, we are currently in arbitration proceedings with seven term SPA customers for the Calcasieu Project and with the Calcasieu EPC Contractor. See “Risk Factors—Risks Relating to Regulation and Litigation—We are involved and may in the future become involved in disputes and legal proceedings,” “Risk Factors—Risks Relating to Regulation and Litigation—If we are unsuccessful in our current and any potential future arbitration proceedings with our customers, the amounts that we are required to pay may be substantial and certain of our post-COD SPAs may be terminated, which may lead to an acceleration of all our debt for the relevant project.” In addition, in 2024 certain of our former employees filed proceedings, including in Virginia federal court, seeking aggregate damages of approximately $214 million with respect to alleged breaches of certain stock option grant agreements and related matters. See “Risk Factors—Risks Relating to Regulation and Litigation—We are involved and may in the future become involved in disputes and legal proceedings.”

Further, from time to time, we may be a party to various administrative, regulatory or other legal proceedings, such as various proceedings before FERC related to our projects. See “Risk Factors—Risks Relating to Regulation and Litigation—We are involved and may in the future become involved in disputes and legal proceedings.”

We are required to assess the likelihood of any adverse judgments or outcomes related to these legal contingencies, as well as potential ranges of probable or reasonably possible losses. We accrue for litigation and claims when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. The determination of the amount of any losses to be recorded or disclosed as a result of these contingencies is based on a careful analysis of each individual exposure with, in some cases, the assistance of outside legal counsel. There can be no assurance that any accrued liabilities will be adequate to cover all existing and future claims or that we will have the liquidity to pay such claims as they arise. If we are unsuccessful in defending ourselves against certain claims by our post-COD SPA customers for the Calcasieu Project described above, the amounts we could be required to pay could be substantial, which could have a material adverse effect on our business, contracts, financial condition, operating results, cash flow, liquidity and prospects.

Other than such foregoing claims, as of the date hereof, there are no pending or threatened legal claims or proceedings, individually or in the aggregate, which we believe could have a material adverse effect on our business or financial condition. For more information, see Note 15 – Commitments and Contingencies in our annual financial statements, included elsewhere in this prospectus.

 

228


Table of Contents

MANAGEMENT

Board of Directors and Executive Officers

Set forth below is certain biographical and other information regarding our directors and executive officers as of September 30, 2024:

 

Name

 

Age

  

Position

Executive Officers     
Michael Sabel   57    Chief Executive Officer, Executive Co-Chairman of the Board, and Founder
Robert Pender   71    Executive Co-Chairman, Executive Co-Chairman of the Board, and Founder
Jonathan Thayer   53    Chief Financial Officer
Brian Cothran   51    Chief Operating Officer
Fory Musser   53    Senior Vice President, Development
Keith Larson   53    General Counsel and Secretary
Thomas Earl   49    Chief Commercial Officer
Non-Employee Directors     
Sari Granat   53    Director
Andrew Orekar   47    Director
Thomas J. Reid   60    Director
Jimmy Staton   63    Director
Roderick Christie   62    Director

Michael Sabel

Michael Sabel is one of the Company’s co-founders. Mr. Sabel has served as the Company’s Chief Executive Officer and as an Executive Co-Chairman of the Company’s board of directors since September 2023. Mr. Sabel has also served as VGLNG’s sole Chief Executive Officer since October 2020 and has served as an Executive Co-Chairman of VGLNG’s board of directors since August 2014. Mr. Sabel was also Managing Partner of Legacy VG Partners since 2012, until Legacy VG Partners merged with the Company, and is currently Managing Partner of VG Partners, the Company’s controlling shareholder. Prior to founding Venture Global, Mr. Sabel spent decades working in the energy, technology and financial service sectors in senior leadership, new company formation, technology licensing and corporate business development. We believe Mr. Sabel is qualified to serve as director due to his experience as one of our co-founders and as our Chief Executive Officer, his decades of experience in capital markets transactions, his comprehensive experience in the energy, energy technology and financial services sectors and his in-depth knowledge of the issues, challenges, and opportunities facing us.

Robert Pender

Robert (Bob) Pender is one of the Company’s co-founders. Mr. Pender has served as an Executive Co-Chairman of the Company’s board of directors since September 2023. Prior to October 2020, Mr. Pender served as Co-Chief Executive Officer of VGLNG. Mr. Pender has also served as an officer of VGLNG as Executive Co-Chairman since October 2020 and as an Executive Co-Chairman of VGLNG’s board of directors since August 2014. Mr. Pender was also Managing Partner of Legacy VG Partners since 2012, until Legacy VG Partners merged with the Company, and is currently Managing Partner of VG Partners, the Company’s controlling shareholder. Mr. Pender previously practiced law for over 28 years, specializing in alternative energy project finance, including during the early years of the sustainable energy transition in the U.S. Mr. Pender has worked on over $35 billion of energy, infrastructure and power projects, including cogeneration, biomass, wind, hydro, geothermal, LNG and nuclear. Prior to founding VGLNG, Mr. Pender previously served as a partner at Hogan Lovells, a global law firm, where he was the Chair and Practice Group Director of its Project &

 

229


Table of Contents

International Finance Group for a decade. Mr. Pender has led large-scale energy infrastructure transactions throughout North America, Central and South America, and South Asia, including representations of nation states, such as the Government of India (through its Ministry of Power), the Republics of Ecuador and Guyana and the Peoples Republic of China (through its SOEs, Sinosure and China Development Bank), lenders, equity investors and developers. Mr. Pender also provided several years of pro bono support to, among others, the American Red Cross for tsunami relief in South Asia, Accion for micro-finance capital projects in Africa and the Republic of Haiti, beginning with legal support to the Interim Haiti Recovery Commission, then serving as a counselor to the Minister Delegate for Energy Security, Republic of Haiti. We believe Mr. Pender is qualified to serve as director due to his experience as one of our co-founders, his decades of experience in law related to alternative energy project finance, and his experience leading large-scale energy infrastructure transactions both domestically and internationally.

Jonathan Thayer

Jonathan (Jack) Thayer has served as the Company’s Chief Financial Officer since September 2023 and has served as VGLNG’s Chief Financial Officer since June 2020. Mr. Thayer has over 25 years of finance, strategy and mergers & acquisition leadership experience including serving as Chief Financial Officer at two Fortune 500 energy companies. Prior to joining VGLNG, he served as Vice Chairman, Corporate Operations and Chief Financial Officer from 2019 to 2020 of Woodward, Inc. (Nasdaq: WWD), an independent designer, manufacturer, and service provider of control system solutions and components for the aerospace and industrial markets, as Chief Financial Officer from 2012 to 2018 of Exelon Corporation (Nasdaq: EXC), a leading utility, power marketing and generation holding company, and, from 2008 to 2012, Chief Financial Officer of Constellation Energy Group, Inc. (Nasdaq: CEG), a large, integrated energy company, with power generation, gas and electric distribution utilities and energy marketing and risk management services. Mr. Thayer has also held roles in investment banking, first with SBC Warburg Dillon Read, and subsequently with Deutsche Bank Securities.

Brian Cothran

Brian Cothran has served as VGLNG’s Chief Operating Officer since September 2020 and will be appointed Chief Operating Officer of the Company in connection with this offering. Mr. Cothran is an accomplished business leader with over 25 years of project, operational and strategic experience in the Oil & Gas and Power Generation industries. Most recently, Mr. Cothran served from 2019-2020 as Chief Executive Officer of The Flexitallic Group, a global market leader in the manufacture and supply of static sealing solutions. Prior to joining Flexitallic, Mr. Cothran served more than 20 years, from 1998-2019, with General Electric (NYSE: GE) and Baker Hughes (Nasdaq: BKR), after its merger with GE Oil & Gas in 2017. During that time, he held a number of senior executive and management roles both in the United States and abroad, which included leading GE’s Energy Services business in Eastern Europe, General Manager of GE’s Flow and Process Technologies business in Europe, Vice President of Global Sales for Baker Hughes and President of GE Oil & Gas North America.

Fory Musser

Fory Musser has served as VGLNG’s Senior Vice President, Development since January 2015 and initially joined VGLNG as its Vice President, Development in September 2014. Mr. Musser will be appointed Senior Vice President, Development of the Company in connection with this offering. Before joining VGLNG, Mr. Musser was the Vice President, Corporate Development for Tervita Corporation, a privately held, leading provider of environmental services to the oil and gas industry in North America. In his four years at Tervita, Mr. Musser’s primary responsibilities included strategic planning, executing corporate acquisitions and divestitures and restructuring the company’s drilling and coring business. Before joining Tervita, Mr. Musser served for more than two years as the Vice President, Strategy for Covanta Energy, one of the world’s largest owners and operators of energy-from-waste facilities. Mr. Musser’s primary responsibilities at Covanta included

 

230


Table of Contents

strategic planning, executing corporate acquisitions, and developing new lines of business that complemented existing operations. Prior to joining Covanta Energy, Mr. Musser worked at AES (NYSE: AES), in a variety of roles, principally focused on project financing, business development, and subsidiary debt restructuring. Before AES, Mr. Musser was a banker in the private placement group at Deutsche Bank Alex Brown.

Keith Larson

Keith Larson has served as the Company’s General Counsel and Secretary since September 2023 and has served as VGLNG’s General Counsel and Secretary since July 2017. Prior to joining VGLNG, Mr. Larson spent 10 years as a partner at Hogan Lovells, a global law firm, where he headed the firm’s infrastructure, energy, resources and projects practice for the Americas. Mr. Larson has over 25 years of experience advising on energy project development, project finance and strategic transactions in the oil and gas sector. Mr. Larson’s prior experience includes serving as Senior Legal Counsel for Shell (NYSE: SHEL) in The Hague.

Thomas Earl

Thomas Earl has served as Chief Commercial Officer of VG LNG Marketing, LLC since 2017 and will be appointed Chief Commercial Officer of the Company in connection with this offering. Prior to joining the Company, Mr. Earl worked for Total (NYSE: TTE) from 1998 to 2017, where he focused on the development of Total’s global LNG business, where he most recently served as head of Total’s North America commodity trading business, including its LNG, gas, power, coal, petcoke and LPG operations, and represented Total in its U.S. LNG liquefaction transactions from 2012 to 2015.

Sari Granat

Sari Granat has served on the Company’s board of directors since September 2023 and has served on VGLNG’s board of directors since January 2022. Ms. Granat has been president and chief operating officer of Chainalysis since 2022, the blockchain data platform, where she has managed the company’s general and administrative functions, including finance, human resources, legal, information security and information technology and the company’s sales organization. At Chainalysis, Ms. Granat works across the firm on strategies to advance the company’s mission of bringing trust and transparency to the global cryptocurrency community. In addition, Ms. Granat currently serves on the board of Assurant, Inc. (NYSE: AIZ), a global provider of risk management products and services, where she serves on the board’s Compensation and Talent Committee and Information Technology Committee. Ms. Granat has also served on the boards of ComplySci, a provider of regulatory technology solutions for the financial services sector, and Opening Act, a nonprofit that advances arts equity by providing free theater programs to New York City’s highest need public schools, the CxO Advisory Council for VMware and on the General Counsel Steering Committee for the National Association of Corporate Directors. From 2012 to 2022, Ms. Granat was with IHS Markit, a formerly NYSE-listed $45+ billion data, analytics and technology company prior to its merger with S&P Global in February 2022, where she most recently served as chief administrative officer and general counsel, leading information security, information technology, legal, risk management, privacy and compliance functions. From 2010 to 2012, Ms. Granat was chief administrative officer and head of business development at TheMarkets.com LLC, a financial technology and data provider. Prior to that role, Ms. Granat has served in a variety of legal and strategy positions with Dow Jones & Company, Kaplan, Inc., Skadden, Arps, Slate, Meagher & Flom LLP, and Kenyon & Kenyon. We believe Ms. Granat is qualified to serve as director due to her significant leadership and management experience within the financial technology and data analytics sectors, including her experience of more than 10 years general counsel of public companies and in risk management, privacy and information technology.

Andrew Orekar

Andrew Orekar has served on the Company’s board of directors since September 2023 and has served on VGLNG’s board of directors since September 2021. Mr. Orekar is the former Chief Executive Officer and Board Member of GasLog Partners (NYSE: GLOP-A), one of the world’s largest LNG shipping companies. Appointed

 

231


Table of Contents

CEO at GasLog Partners’ founding in 2014, Mr. Orekar led the company’s IPO and oversaw its growth from three to fifteen vessels during his nearly seven years as CEO. Mr. Orekar worked at GasLog Partners in his capacity as CEO until 2020. Prior to joining GasLog Partners, Mr. Orekar served as Managing Director at Goldman, Sachs & Co., where he advised natural resources companies on mergers and acquisitions and capital markets transactions. Mr. Orekar joined Goldman Sachs in 1998 and held several leadership positions in the investment banking division. Mr. Orekar also previously served on the boards of directors of Tortoise Acquisition Corp. and Parabola Acquisition Corp. We believe Mr. Orekar is qualified to serve as director due to his extensive public company leadership experience in the LNG and maritime transport sectors and his deep knowledge of corporate transactions within the energy, shipping and financial services industries.

Thomas J. Reid

Thomas Reid has served on the Company’s board of directors since September 2023 and has served on VGLNG’s board of directors since January 2022. Mr. Reid is chief legal officer and secretary of Comcast Corporation (Nasdaq: CMCSA), a position he has held since April 2019. Mr. Reid oversees Comcast’s legal, corporate governance and strategic intellectual property functions and the company’s government and regulatory affairs and political affairs functions. Mr. Reid joined Comcast in 2019 after a successful career at Davis Polk & Wardwell, LLP. Mr. Reid began his career there in 1987 and served as chairman and managing partner of the firm from 2011 until his transition to Comcast. Mr. Reid also served as a Managing Director in the Investment Banking division of Morgan Stanley from 2000-2003. Mr. Reid’s private legal practice and banking career were heavily focused on the global energy and utilities sector, advising on privatizations, mergers and acquisitions, financings and board investigations for leading international oil and gas companies and national oil companies. Mr. Reid serves as trustee for the Archdiocese of New York’s Inner-City Scholarship Fund and as a trustee of the National Urban League. We believe Mr. Reid is qualified to serve as director due to his extensive leadership experience in legal advisory roles, including his role at public companies, law firms, and investment banks, as well as his deep knowledge of the global energy and utilities sector.

Jimmy Staton

Jimmy Staton has served on the Company’s board of directors since September 2023 and has served on VGLNG’s board of directors since August 2014. Mr. Staton was formerly VGLNG’s Executive Vice President from January 2015 to November 2016. Mr. Staton is currently the President and Chief Executive Officer of the South Carolina Public Service Authority (Santee Cooper), a state owned electric and water utility company that provides power directly or indirectly to 2 million South Carolinians and clean water to over 200,000 customers, and has served in such capacity since March 2022. Prior to this, Mr. Staton served as President and CEO of Southern Star Central Corporation, a privately held natural gas pipeline company with assets throughout the Midwest United States, from 2017 to 2022. Additionally, Mr. Staton also served as Executive Vice President and Group CEO for NiSource, Inc. (NYSE: NI) from 2008 to 2014. Prior to his tenure at NiSource, Mr. Staton held several senior executive level positions at Dominion Resources, Inc. (NYSE: D) from 1993 to 2008. Mr. Staton has also been active in industry organizations having served on the Board of Directors for the Edison Electric Institute, the Interstate Natural Gas Association of America, the American Gas Association, the American Gas Foundation and the Southern Gas Association. We believe Mr. Staton is qualified to serve as director due to his extensive experience in the utilities sector, including leadership roles in gas distribution, electric and gas utilities and interstate gas pipelines businesses.

Roderick Christie

Roderick Christie has served on the Company’s board of directors since September 2023 and has served on VGLNG’s board of directors since June 2023. Mr. Christie is a veteran of the electricity and energy sectors, with over 30 years of international experience. From September 2022 to January 2023, Mr. Christie was Executive Vice President of Baker Hughes (Nasdaq: BKR), Industrial & Energy Technology business where he worked with business developments, manufactures and services of a wide range of technologies for the energy, aviation

 

232


Table of Contents

and automotive industries. Prior to that, from January 2016 to September 2022, Mr. Christie was Executive Vice President of Baker Hughes Turbomachinery and Process Solutions business. In 2017, Mr. Christie created and led the Baker Hughes Climate Technology Solutions, developing solutions for hydrogen, CCUS, integrated clean energy, and emissions management to support customers’ net-zero emission ambitions and latterly integrated the Baker Hughes Controls, Sensing and Diagnostics businesses to create the Baker Hughes Industrial & Energy Technology Business. From June 2018 to February 2023, Mr. Christie served as a member of the board at Aero Alliance Products & Services LLC. Prior to Baker Hughes, Mr. Christie was President & CEO of GE Energy Subsea Solutions from June 2011 to December 2016, President of GE Energy Central & Eastern Europe, Russia and Central Asia from September 2004 to June 2011 and CEO of GE Energy Services Europe from June 1999 to September 2004. Before joining GE, he worked for 14 years at Scottish & Southern Energy (LSE: SSE) in the utility power sector, where he held a wide range of engineering, project development and management roles. Accordingly, Mr. Christie has developed significant global experience in the oil & gas, gas processing, LNG, refining, petrochemical and electricity sectors. We believe Mr. Christie is qualified to serve as director due to his decades of international experience in the electricity and energy sectors, and his extensive public company leadership experience within the energy industry.

Other Key Employees

Set forth below is certain biographical and other information regarding our other key employees as of September 30, 2024:

 

Name

 

Age

  

Position

Leah Woodward   39    Treasurer and Managing Director
Sarah Blake   49    Senior Vice President and Chief Accounting Officer
Ngoni Murandu   50    Chief Information Officer

Leah Woodward

Leah Woodward has served as the Company’s Treasurer since September 2023 and has served as VGLNG’s Treasurer and Managing Director since January 2020 and June 2017, respectively, and oversees Venture Global’s capital markets, treasury, corporate strategy and development, and investor relations activities. Ms. Woodward has more than 18 years of experience across the capital structure and has worked with Venture Global’s founders since 2014 to raise approximately $54 billion of capital for the business. This includes the Calcasieu Pass and Plaquemines project financings, representing more than $29 billion of total investment, as well as more than $15 billion of high-yield bond issuances. Prior to joining Venture Global, from 2009 to 2017, Ms. Woodward was a Managing Director and the Head of Institutional Sales at Height Capital Markets, a Washington, D.C.-based broker-dealer and investment bank, and in that capacity worked on Venture Global’s inaugural capital raises. Before joining Height Capital Markets, Ms. Woodward worked in fixed income at BNP Paribas, a global bank, from 2006 until 2008. She earned her Chartered Financial Analyst (CFA) charter in 2010.

Sarah Blake

Sarah Blake has served as VGLNG’s Senior Vice President and Chief Accounting Officer since January 2020, and focuses on financial transformation, SEC reporting and technical accounting. Ms. Blake will be appointed Senior Vice President and Chief Accounting Officer of the Company in connection with this offering. Ms. Blake has over 25 years of accounting experience across a wide range of businesses and firms. Prior to joining VGLNG, Ms. Blake served in various capacities at The AES Corporation (NYSE: AES) from 2006 to 2020, most recently in her capacity as Vice President, Controller and Chief Accounting Officer from 2017 to 2020. Ms. Blake currently is a licensed Certified Public Accountant in Virginia.

Ngoni Murandu

Ngoni Murandu has served as VGLNG’s Chief Information Officer since August 2019 and will be appointed Chief Information Officer in connection with this offering. He focuses particularly on information

 

233


Table of Contents

technology systems in the energy sector. Mr. Murandu has over 25 years of experience in the information technology industries, and has installed, maintained and managed large enterprise resource applications for a wide range of businesses. Prior to joining VGLNG, Mr. Murandu served as the Vice President of Information Technology Services and the Chief Information Officer at Southwest Gas Corporation (NYSE: SWX) from May 2017 to August 2019. Prior to Southwest Gas Corporation, Mr. Murandu served as the Vice President and Chief Information Officer at NW Natural (NYSE: NWN) from May 2014 to May 2017.

Family Relationships

There are no family relationships among any of the directors or executive officers.

Status as a “Controlled Company” under the NYSE Listing Standards

After the completion of this offering, VG Partners will continue to hold approximately   % of the total combined voting power of our Class A common stock and Class B common stock eligible to vote in the election of directors (or approximately  % of the total combined voting power if the underwriters exercise in full their option to purchase additional shares of Class A common stock). As a result, we will be a “controlled company” for the purposes of the NYSE listing requirements.

As a “controlled company,” we may elect not to comply with certain corporate governance standards under the rules of the NYSE, including the requirements (i) that a majority of our board of directors consist of independent directors, (ii) that our board of directors have a compensation committee that is comprised entirely of independent directors with a written charter addressing the committee’s purpose and responsibilities, (iii) that our board of directors have a nominating and governance committee that is comprised entirely of independent directors with a written charter addressing the committee’s purpose and responsibilities, and (iv) that our board of directors conduct an annual performance evaluation of the nominating and governance committee and the compensation committee. For at least some period following this offering, we intend to utilize these exemptions.

Consistent with these exemptions, upon closing this offering, we will not have an independent compensation committee or an independent nominating and corporate governance committee. However, despite being a “controlled company,” we are required to comply with the rules of the SEC and the NYSE relating to the membership, qualifications and operations of the audit committee. Upon closing this offering, we will have a fully independent audit committee. Additionally, we have adopted charters for our audit, compensation, nominating and governance committees and intend to conduct annual performance evaluations of these committees.

Accordingly, although we may transition to fully independent compensation and nominating and governance committees prior to the time we cease to be a “controlled company,” for such period of time you will not have the same protections afforded to shareholders of companies that are subject to all of these corporate governance requirements. In the event that we cease to be a “controlled company” and our shares continue to be listed on the NYSE, we will be required to comply with these provisions within the applicable transition periods.

Board Structure and Compensation of Directors

Board Composition

Our amended and restated bylaws will provide that the board of directors shall initially consist of not less than three directors, nor more than eleven directors, and the number of directors may be changed only by resolution of the board of directors; provided, however, that prior to the Trigger Date our stockholders may also fix the number of directors. Upon completion of the offering, our board of directors will consist of seven members.

Initially, our board of directors will consist of a single class of directors each serving one year terms. After the Trigger Date, our board of directors will be divided into three classes of directors, with each class as nearly equal in number as possible, serving staggered three-year terms (other than directors which may be elected by holders of preferred stock, if any). This classification of our board of directors could have the effect of increasing the length of time necessary to change the composition of a majority of the board of directors because, in general, at least two annual meetings of stockholders would be necessary for stockholders to effect a change in a majority of the members of the board of directors.

 

234


Table of Contents

Director Independence

We intend to avail ourselves of the “controlled company” exception under the NYSE rules, which allows us to elect not to comply with the requirements that a listed company must have a majority of independent directors on its board of directors and that its compensation and nominating and governance committees be composed entirely of independent directors. Notwithstanding such election, our board of directors has reviewed the materiality of any relationship that each of our directors has with us, either directly or indirectly. Based on this review, our board has determined that each of Sari Granat, Andrew Orekar, Thomas J. Reid, Jimmy Staton and Roderick Christie is “independent” as that term is defined under the applicable rules and regulations of the SEC and the listing standards of the NYSE.

Board Committees

Following the completion of this offering, our board will establish three standing committees – audit, compensation and nominating and governance—each of which will operate under a charter that will be approved by our board. Current copies of each committee’s charter will be posted on the Corporate Governance section of our website at www.ventureglobal.com. Our website and the information contained therein or connected thereto shall not be deemed to be incorporated into this prospectus or the registration statement of which it forms a part and is included in this prospectus as an inactive textual reference only.

Audit Committee

The members of our audit committee will be Roderick Christie, Andrew Orekar and Jimmy Staton, with Andrew Orekar serving as the chairman of our audit committee. Each member of our audit committee has been determined by the board to satisfy the independence requirements for audit committee members under the listing standards of the NYSE and Rule 10A-3 of the Exchange Act, and to meet the financial literacy requirements under the rules and regulations of the NYSE and the SEC. In addition, our board of directors has determined that each of Roderick Christie, Andrew Orekar and Jimmy Staton is an “audit committee financial expert” as defined in Item 407(d)(5)(ii) of Regulation S-K promulgated under the Securities Act of 1933, as amended, or the Securities Act. This designation does not impose on him or her any duties, obligations or liabilities that are greater than are generally imposed on members of our audit committee and our board of directors. Our audit committee is directly responsible for, among other things:

 

   

selecting a firm to serve as the independent registered public accounting firm to audit our financial statements;

 

   

ensuring the independence of the independent registered public accounting firm;

 

   

discussing the scope and results of the audit with the independent registered public accounting firm and reviewing, with management and that firm, our interim and year-end operating results;

 

   

establishing procedures for employees to anonymously submit concerns about questionable accounting or audit matters;

 

   

considering the adequacy of our internal controls and internal audit function;

 

   

reviewing material related party transactions or those that require disclosure; and

 

   

approving or, as permitted, pre-approving all audit and non-audit services to be performed by the independent registered public accounting firm.

Our audit committee will operate under a written charter, to be effective immediately prior to the closing of this offering, that satisfies the applicable rules of the SEC and the listing standards of the NYSE.

Compensation Committee

The members of our compensation committee will be Robert Pender, Michael Sabel and Thomas Reid, with Michael Sabel serving as the chairman of our compensation committee. Our compensation committee is responsible for, among other things:

 

   

reviewing and approving, or recommending that our board of directors approve, the compensation of our executive officers;

 

235


Table of Contents
   

reviewing and recommending to our board of directors the compensation of our directors;

 

   

administering our stock and equity incentive plans;

 

   

reviewing and approving, or making recommendations to our board of directors with respect to, incentive compensation and equity plans; and

 

   

reviewing our overall compensation philosophy.

Our compensation committee will operate under a written charter, to be effective immediately prior to the closing of this offering, that satisfies the applicable rules of the SEC and the listing standards of the NYSE.

Nominating and Governance Committee

The members of our nominating and governance committee are Robert Pender, Michael Sabel and Sari Granat, with Michael Sabel serving as the chairman of our nominating and governance committee. Our nominating and governance committee is responsible for, among other things:

 

   

identifying and recommending candidates for membership on our board of directors;

 

   

reviewing and recommending our corporate governance guidelines and policies;

 

   

reviewing proposed waivers of the code of conduct for directors and executive officers;

 

   

overseeing the process of evaluating the performance of our board of directors; and

 

   

assisting our board of directors on corporate governance matters.

Our nominating and governance committee will operate under a written charter, to be effective immediately prior to the closing of this offering, that satisfies the applicable rules of the SEC and the listing standards of the NYSE.

Code of Ethics

In connection with this offering, our board of directors will adopt a code of ethics that applies to all of our employees, officers and directors, including our Co-Chairmen, Chief Executive Officer, Chief Financial Officer and other executive and senior financial officers, in accordance with applicable U.S. federal securities laws and the corporate governance rules of NYSE. Upon completion of this offering, the full text of our codes of business conduct and ethics will be posted on the investor relations section of our website. We intend to disclose future amendments to our codes of business conduct and ethics, or any waivers of such code, on our website or in public filings.

Corporate Governance Guidelines

Our board of directors has adopted corporate governance guidelines in accordance with the corporate governance rules of the NYSE.

Compensation Committee Interlocks and Insider Participation

None of our executive officers has served as a member of a compensation committee (or if no committee performs that function, the board of directors) of any other entity that has an executive officer serving as a member of our board of directors.

To the extent any members of our compensation committee and affiliates of theirs have participated in transactions with us, a description of those transactions is described in “Certain Relationships and Related Person Transactions.”

 

236


Table of Contents

EXECUTIVE COMPENSATION

Compensation Discussion and Analysis

The purpose of this Compensation Discussion and Analysis section is to provide information about the material elements of compensation that, during our fiscal year ended December 31, 2023, were paid to, awarded to, or earned by our “named executive officers”, or NEOs, who consist of our Chief Executive Officer, our Chief Financial Officer and our three other most highly compensated executive officers during our 2023 fiscal year.

Our named executive officers for fiscal year 2023 are:

 

   

Michael Sabel, Chief Executive Officer, Founder, and Executive Co-Chairman of the Board and Director;

 

   

Jonathan Thayer, Chief Financial Officer;

 

   

Robert Pender, Executive Co-Chairman, Founder, and Executive Co-Chairman of the Board and Director;

 

   

Thomas Earl, Chief Commercial Officer; and

 

   

Keith Larson, General Counsel and Secretary.

As noted above, this Compensation Discussion and Analysis section describes our historical executive compensation program for our named executive officers during our 2023 fiscal year. In connection with this offering, we intend to adopt compensation plans typical for public companies and we expect that, after this offering, our compensation committee will set policies and practices that may be different from the policies and practices that applied to our executive officers before this offering.

Our Compensation Philosophy

Our Company strives to be a leader in compensation relative to our industry peers in order to attract the best talent, and our executive compensation programs are designed to attract, motivate and retain a highly talented senior management team capable of deploying best-in-class industry expertise to deliver competitively priced, reliable and clean North American LNG exports on a growing scale. The following principles help guide us in designing our pay programs toward this end:

 

   

Competitive Pay: Our goal is to attract and maintain the best talent in our industry by paying above-market total compensation. We will review “market” total compensation and, over time, target each executive competitively within the market based upon our assessment of a variety of factors including individual performance, Company-wide performance, time in role, individual skills and importance of the role. Generally, our philosophy is to place more compensation in cash-based incentive opportunities, which are tied to key project-based milestones reflecting our long-term business objectives, as well as year-over-year individual performance goals. As noted above, actual pay delivered will vary based on both Company-wide and individual performance. The elements of our compensation programs are discussed in greater detail below.

 

   

Significant Pay at Risk: As noted above, a significant portion of the total compensation of our executives should be variable and at risk, which is primarily accomplished through our cash and equity incentive compensation programs. We will pay our NEOs higher compensation when they exceed our goals and lower compensation when they do not meet our goals.

 

   

Alignment with Shareholder Interests: The interests of our executives should align with the interests of our stockholders. Our short- and long-term incentive compensation programs utilize a performance-based mentality that correlates well with the creation of stockholder value.

 

237


Table of Contents
   

Support Business Strategy: Our executive compensation programs are aligned with our short-term and long-term business objectives, business strategy and Company-wide financial and operational performance, furthering the creation of stockholder value.

 

   

Risk Management: We believe that our compensation policies and practices appropriately balance near-term performance improvement with sustainable long-term value creation and that they do not encourage unnecessary or imprudent risk taking. We continuously evaluate the design of all our compensation policies and practices, including our incentive plans, to assess whether they encourage employees to take appropriate risks and discourage taking inappropriate risks.

Compensation Process

Historically, the compensation of our Founders, Messrs. Sabel and Pender, has been set by our Board and, since October 2020, the compensation of our executive officers other than the Founders has been set by Mr. Sabel in his capacity as our Chief Executive Officer. In anticipation of becoming a public company, our Board will adopt a written charter for the compensation committee that establishes, among other things, the compensation committee’s purpose and its responsibilities with respect to executive compensation. The charter of the compensation committee will provide that the compensation committee shall, among other things, review and approve, or recommend to our Board, as appropriate, executive officer compensation, and otherwise assist our Board in its oversight of executive compensation, management development and succession, director compensation and executive compensation disclosure.

In connection with becoming a public company, we intend to engage an outside compensation consultant to advise the compensation committee with respect to go-forward executive compensation programs, policies and decisions.

Elements of Compensation

Historically, our executive compensation programs have consisted of the following elements: base salary, short- and long-term, as well as milestone-based, cash incentive compensation, equity incentive compensation, health, welfare and retirement benefits and perquisites, each established as part of our programs in order to achieve our compensation objectives.

Annual Base Salary

Base salary is intended to fairly compensate our NEOs for the responsibilities of their respective positions and achieve an optimal balance of fixed and variable pay. In setting the salaries of individual NEOs, we consider a wide range of factors including the scope of the NEO’s role, experience, skillsets and the compensation paid for similar positions at other companies similar to ours. The base salaries for our NEOs as of December 31, 2023 were as follows:

 

Name

   2023 Base
Salary

Michael Sabel

   $7,500,000(1)

Jonathan Thayer

   $1,500,000

Robert Pender

   $3,500,000(1)

Thomas Earl

   $1,500,000

Keith Larson

   $1,500,000

 

(1)

In 2023, each of Mr. Sabel and Mr. Pender received a base salary for services he provided to certain of our subsidiaries, which were paid by each such subsidiary. These amounts reflect the aggregate base salary rates in effect as of December 31, 2023.

 

238


Table of Contents

Cash Incentive Compensation Arrangements

In order to incentivize and reward performance, we maintain various cash incentive opportunities for our executives, including our NEOs, which pay out based on the achievement of certain financial and operating performance objectives and our key strategic priorities. We believe these opportunities reflect a well-balanced framework for motivating our key personnel to execute on our strategic priorities while being recognized for their individual contributions to our short- and long-term growth. In connection with this offering, we intend to adopt a management cash incentive plan which will govern the grant of cash-based incentive compensation for performance periods beginning after the completion of this offering.

Annual Cash Performance Bonus

Our NEOs are eligible to receive cash-based annual performance bonuses based on a qualitative evaluation of individual and Company performance following the applicable performance year, including with respect to achievement of strategic milestones and financial performance. At the end of each year, the Chief Executive Officer assesses such performance and provides a recommendation to our Board as to each NEO’s annual performance bonus amount, including his own. The Company believes that this approach provides an opportunity to balance our annual financial and operational achievements with qualitative judgments regarding how individual performance goals were achieved and ensures appropriate and balanced outcomes once all relevant facts are known following the end of a fiscal year. As the Company matures over time, the compensation committee will continue to evaluate its compensation programs and criteria with a focus on aligning short-term incentive compensation to achievement of performance-specific outcomes for a given year. Annual performance bonuses are generally payable in April of the year following the year for which the bonus is earned, subject to the NEO’s continued employment with us through the payment date. Annual performance bonuses earned by our NEOs for the 2023 fiscal year were as follows:

 

Name

   2023 Bonus

Michael Sabel

   $25,000,000

Jonathan Thayer

   $2,000,000

Robert Pender

   $25,000,000

Thomas Earl

   $2,000,000

Keith Larson

   $2,000,000

Project Milestone Bonuses

Project Milestone Bonuses constitute an important part of our compensation philosophy by rewarding successful completion of key strategic objectives.

Each NEO is eligible to earn certain cash bonuses, or Project Milestones Bonuses, upon the successful completion of significant milestones with respect to the development of our natural gas liquefaction and export facilities. For each export facility project or phase thereof, a Project Milestone Bonus is earned upon the completion of three milestones as follows:

 

   

FID: Earned upon the Board’s determination that, with respect to any project or phase thereof, the following conditions have been satisfied: (i) the project has received all necessary regulatory authorizations, including from FERC, to commence construction; (ii) the project has secured sufficient financing for construction and funds are available from lenders for disbursement thereunder; and (iii) the project has received approval from the Board to proceed with the construction.

 

   

LPS: Earned on the date on which, with respect to any project or phase thereof, the performance acceptance tests for a certain number of liquefaction trains of the project or phase thereof have been successfully passed and such liquefaction trains have initiated continuous operation producing liquefied natural gas for sale.

 

   

COD: Earned as of COD for the relevant project or phase thereof.

 

239


Table of Contents

Project Milestone Bonuses are generally payable in connection with the completion of each milestone noted above, subject in each case to the NEO’s continued employment through such date. In certain cases, the bonuses are paid in equal quarterly installments over a one-year period, subject to the NEO’s continued employment through each payment date.

The following table sets forth, for each of our NEOs, the aggregate Project Milestone Bonus opportunity as of January 1, 2023, any amounts awarded in 2023, any amounts paid in 2023, and the outstanding bonus opportunity as of December 31, 2023. In 2023, Project Milestone Bonuses were outstanding with respect to the Calcasieu Project, the Plaquemines Project, the CP2 Project and/or the Delta Project.

 

Name

   Outstanding
as of January 1,
2023
   Granted in
2023
   Paid in 2023   Outstanding
as of
December 31,
2023

Michael Sabel

   $3,000,000    $15,000,000    $1,000,000(1)   $17,000,000

Jonathan Thayer

   $10,000,000    $5,000,000    $1,000,000(1)   $14,000,000(4)

Robert Pender

   $3,000,000    $15,000,000    $1,000,000(1)   $17,000,000

Thomas Earl

   $8,250,000    $4,000,000    $1,250,000(2)   $11,000,000(4)

Keith Larson

   $10,125,000    $5,000,000    $1,125,000(3)   $14,000,000(4)

 

(1)

Represents a lump sum payment of a Project Milestone Bonus earned in 2023.

(2)

$1,000,000 of this amount represents a lump sum payment of a Project Milestone Bonus earned in 2023 and $250,000 of this amount represents the final installment payment of a $1,000,000 Project Milestone Bonus which was paid out in four equal quarterly installments over a 12-month period.

(3)

$1,000,000 of this amount represents a lump sum payment of a Project Milestone Bonus earned in 2023 and $125,000 of this amount represents the final installment payment of a $500,000 Project Milestone Bonus which was paid out in four equal quarterly installments over a 12-month period.

(4)

Each Project Milestone Bonus that becomes earned will be paid in four equal quarterly installments over a 12-month period, except in the case of Mr. Thayer, who received certain Project Milestone Bonuses in 2020 (totaling $9,000,000 of the outstanding amount reported in the table), which will be paid within 45 days of completion of each milestone.

Strategic Recognition Awards

The Company has also granted strategic recognition awards to the NEOs, other than Messrs. Sabel and Pender, which are structured as deferred bonus awards designed to motivate sustained service with us over an extended period, or the Strategic Recognition Awards. In 2022 and 2023, each of Messrs. Thayer, Earl and Larson received a Strategic Recognition Award in the amount of $2,000,000 and $3,000,000, respectively. The Strategic Recognition Awards are payable in equal quarterly installments over a four-year period, subject to the NEO’s continued employment with us through each payment date. The Strategic Recognition Awards earned by each such NEO in 2023 was as follows:

 

Name

   Strategic
Recognition
Awards Paid in
2023

Jonathan Thayer

   $875,000

Thomas Earl

   $875,000

Keith Larson

   $875,000

Major Revenue Contract Bonuses

Another element of our compensation philosophy is recognizing the accomplishments of employees in contributing to our sustained long-term growth and development. Accordingly, we compensate employees who

 

240


Table of Contents

primarily focus on marketing our business for their critical roles in negotiating and successfully executing major revenue contracts for liquefied natural gas, or Revenue Contract Bonus.

Of our NEOs, only Mr. Earl is eligible to receive a Revenue Contract Bonus. The Revenue Contract Bonus is earned upon execution of a sales and purchase agreement pursuant to which a specified amount of liquefied natural gas is committed to be purchased over an extended contract term. Payment of the bonus is subject to Mr. Earl’s continued employment on the date of execution of such contract and payable within 30 days thereof.

In 2023, Mr. Earl earned aggregate Revenue Contract Bonuses in the amount of $695,000.

Long-Term Equity Incentive Compensation

We view long-term equity incentive compensation as a critical component of our balanced total compensation program and a primary means to incentivize our employees to contribute to the long-term growth and development of our business. For us, this has historically taken the form of non-qualified stock option grants under the Venture Global LNG, Inc. 2014 Stock Option Plan, as amended and restated from time to time, or the 2014 Plan, and its successor plan, the Amended and Restated Venture Global, Inc. 2023 Stock Option Plan, or the 2023 Plan. In connection with the Reorganization Transactions, all options that were previously granted and outstanding under the 2014 Plan were converted, on a one-for-one basis, into stock options with respect to shares of our Class A common stock under the 2023 Plan and remain outstanding under the 2023 Plan. The material terms of the 2023 Plan are described under “—2023 Stock Option Plan” below.

Stock options granted to our NEOs pursuant to our equity incentive program vest in equal quarterly installments over a four-year period from the grant date, subject to the executive’s continued employment with us through each vesting date and expire on the 10th anniversary of the grant date. In 2023, none of our NEOs received a grant of stock options under the 2014 Plan or the 2023 Plan.

In connection with this offering, subject to approval by our Board and stockholders, we intend to adopt the Venture Global, Inc. 2024 Omnibus Incentive Plan, or the Omnibus Incentive Plan, under which our employees (including our NEOs) may receive long-term incentive compensation in the future. The material terms of the Omnibus Incentive Plan are described under “—2024 Omnibus Incentive Plan” below.

Other Benefits and Perquisites

We provide benefits, including personal benefits and perquisites, to our NEOs as summarized below. We believe that these benefits are necessary and appropriate to enable us to attract and retain top talent within a competitive marketplace and to facilitate the performance of our NEOs’ management responsibilities.

Personal Security

We provide personal security services for Mr. Sabel, which is based on an assessment of risk in light of his position as our Chief Executive Officer. These services generally include security systems at Mr. Sabel’s residence, security services and personnel at his residences and/or during personal travel and car and personal security driver. While we do not consider these security costs to be personal benefits since they arise from the nature of Mr. Sabel’s employment with our Company, certain amounts that are paid by us are considered to constitute perquisites and personal benefits for purposes of SEC disclosure rules and are reported in the Summary Compensation Table under the “All Other Compensation” column below based on the aggregate incremental cost to the Company to provide these services.

Corporate Aircraft Policy

We encourage use of our corporate aircraft for the personal travel of our Co-Chairmen and Founders because it increases their time available for business purposes and enhances their safety and security. The

 

241


Table of Contents

aggregate incremental cost to us for personal use of the corporate aircraft and the total number of hours the NEO used the aircraft in 2023, calculated based on the hourly variable cost rate for personal use of the aircraft, including fuel, airport fees, crew expenses and in-flight catering is reported in the Summary Compensation Table under the “All Other Compensation” column below.

Retirement and Health and Welfare Benefits

We maintain a tax-qualified defined contribution plan, or the 401(k) Plan, in which our employees, including our NEOs (other than Mr. Earl), are eligible to participate. Under the 401(k) Plan, participants may defer a portion of their annual compensation on a pre-tax basis, and we will make matching contributions of 100% of the first 6% of a participant’s deferrals. All of our full-time employees, including our NEOs, are also eligible to participate in customary health and welfare plans, except for Mr. Earl, who is based in the UK. In lieu of his participation in the health and welfare plans generally available to our employees, we provide Mr. Earl with a monthly stipend in the amount of $3,000 to cover his health and welfare expenses. In addition, we provided contributions to Mr. Earl’s pension in an amount equal to $1,640 in 2023.

Executive Employment Agreements

Michael Sabel

On     , 2024, we (through our operating subsidiary, VGLNG) entered into an employment agreement with Mr. Sabel, which will become effective in connection with this offering, under which he will continue to serve as our Chief Executive Officer, reporting to the Board. The agreement provides for an indefinite employment term which may be terminated by either party at any time for any reason.

The employment agreement provides for Mr. Sabel’s annual base salary of $7,500,000, participation in our annual incentive compensation program, as in effect from time to time, receipt of Project Milestone Bonuses (as described under “Elements of Compensation – Cash Incentive Compensation Arrangements – Project Milestone Bonuses” above), eligibility to participate in our omnibus long-term incentive plan, as in effect from time to time, and participation in our benefit plans. In addition, Mr. Sabel is entitled to use the corporate aircraft in accordance with our aircraft use policy and use personal security protective services offered by us and at our expense.

In the event of a termination of Mr. Sabel’s employment for any reason, including due to his death or “disability” (as defined in the agreement), he will solely be entitled to receive certain accrued compensation and benefits.

The employment agreement is governed under the laws of the State of Virginia.

Jonathan Thayer

On     , 2024, we (through our operating subsidiary, VGLNG) entered into an employment agreement with Mr. Thayer, which will become effective in connection with this offering, under which he will continue to serve as our Chief Financial Officer, reporting to the Chief Executive Officer. The agreement provides for an indefinite employment term which may be terminated by either party at any time for any reason.

The employment agreement provides for Mr. Thayer’s annual base salary of $1,500,000, participation in our annual incentive compensation program, as in effect from time to time, receipt of Project Milestone Bonuses (as described under “Elements of Compensation – Cash Incentive Compensation Arrangements – Project Milestone Bonuses” above), receipt of Strategic Recognition Awards (as described under “Elements of Compensation – Cash Incentive Compensation Arrangements – Strategic Recognition Awards” above), eligibility to participate in our omnibus long-term incentive plan, as in effect from time to time, and participation in our benefit plans.

 

242


Table of Contents

In the event of a termination of Mr. Thayer’s employment by us without “cause” (a defined in the employment agreement) or as the direct result of a “change in control” (as defined below), he will receive, subject to his execution and non-revocation of a release of claims, a lump sum payment equal to his base salary for the year in which the termination date occurs, payable within 60 days of termination date. Under the agreement, a “change in control” is defined as both Messrs. Sabel and Pender ceasing to control possession, directly or indirectly, of the power to direct or cause the direction of the management of our Company, whether through the ownership of voting securities, by agreement or otherwise.

In the event of a termination of Mr. Thayer’s employment for any other reason, including due to his death or “disability” (as defined in the agreement), he will solely be entitled to receive certain accrued compensation and benefits, and he will be deemed to have resigned from all position he holds as an officer or director with us or any of our affiliates.

As a condition of his employment, Mr. Thayer is subject to the restrictions set forth in a restrictive covenant agreement entered into with us, the terms of which are subscribed under “—Restrictive Covenant Agreements” below.

The employment agreement is governed under the laws of the State of Virginia.

Robert Pender

On     , 2024, we (through our operating subsidiary, VGLNG) entered into an employment agreement with Mr. Pender, which will become effective in connection with this offering, under which he will continue to serve as our Executive Co-Chairman, reporting to the Board. The agreement provides for an indefinite employment term which may be terminated by either party at any time for any reason.

The employment agreement provides for Mr. Pender’s annual base salary of $3,500,000, participation in our annual incentive compensation program, as in effect from time to time, receipt of Project Milestone Bonuses (as described under “Elements of Compensation – Cash Incentive Compensation Arrangements – Project Milestone Bonuses” above), eligibility to participate in our omnibus long-term incentive plan, as in effect from time to time, and participation in our benefit plans. In addition, Mr. Pender is entitled to use the corporate aircraft in accordance with our aircraft use policy and use personal security protective services offered by us and at our expense.

In the event of a termination of Mr. Pender’s employment for any reason, including due to his death or “disability” (as defined in the agreement), he will solely be entitled to receive certain accrued compensation and benefits.

The employment agreement is governed under the laws of the State of Virginia.

Thomas Earl

On     , 2024, we (through the UK branch of our operating subsidiary, VG LNG Marketing, LLC), entered into an amended and restated services agreement with Mr. Earl, which will become effective in connection with this offering, under which he will continue to provide services as our Chief Commercial Officer, reporting to the Chief Executive Officer. The agreement provides for an indefinite employment term which may be terminated by either party at any time with not less than three months’ written notice. All compensation paid to Mr. Earl is earned in U.S. dollars and paid in British pounds using the applicable exchange rates in effect as of the date the compensation is earned.

The services agreement provides for Mr. Earl’s annual salary at the rate of the British pound equivalent of $1,500,000, eligibility to receive discretionary bonuses, receipt of Project Milestone Bonuses (as described under

 

243


Table of Contents

“Elements of Compensation – Cash Incentive Compensation Arrangements – Project Milestone Bonuses” above), receipt of Strategic Recognition Awards (as described under “Elements of Compensation – Cash Incentive Compensation Arrangements – Strategic Recognition Awards” above), eligibility to participate in our omnibus long-term incentive plan, as in effect from time to time, and eligibility to participate in our pension scheme. In addition, we will pay Mr. Earl $3,000 per month in lieu of the provision of any benefits.

Mr. Earl’s employment may be terminated by us at any time by providing three months’ written notice, or by providing payment in the lieu of the notice period in an amount equal to Mr. Earl’s base salary for such period, and he will be deemed to have resigned from all position he holds as an officer or director with us or any of our affiliates. In the event of a termination of employment due to his illness, accident or other incapacity, he will receive such remuneration as the Board in its discretion allows.

Mr. Earl is subject to the restrictions set forth in a restrictive covenant agreement entered into with us, the terms of which are subscribed under “—Restrictive Covenant Agreements” below.

The services agreement is governed under English law.

Keith Larson

On      , 2024, we (through our operating subsidiary, VGLNG) entered into an employment agreement with Mr. Larson, which will become effective in connection with this offering, under which he will continue to serve as our General Counsel and Secretary, reporting to the Chief Executive Officer. The agreement provides for an indefinite employment term which may be terminated by either party at any time for any reason.

The employment agreement provides for Mr. Larson’s annual base salary of $1,500,000, participation in our annual incentive compensation program, as in effect from time to time, receipt of Project Milestone Bonuses (as described under “Elements of Compensation – Cash Incentive Compensation Arrangements – Project Milestone Bonuses” above), receipt of Strategic Recognition Awards (as described under “Elements of Compensation – Cash Incentive Compensation Arrangements – Strategic Recognition Awards” above), eligibility to participate in our omnibus long-term incentive plan, as in effect from time to time, and participation in our benefit plans.

In the event of a termination of Mr. Larson’s employment for any reason, including due to his death or “disability” (as defined in the agreement), he will solely be entitled to receive certain accrued compensation and benefits, and he will be deemed to have resigned from all position he holds as an officer or director with us or any of our affiliates.

As a condition of his employment, Mr. Larson is subject to the restrictions set forth in a restrictive covenant agreement entered into with us, the terms of which are subscribed under “—Restrictive Covenant Agreements” below.

The employment agreement is governed under the laws of the State of Virginia.

Restrictive Covenant Agreements

Each of our NEOs, other than Messrs. Sabel and Pender, is party to a restrictive covenant agreement, which generally provides for restrictions on non-competition (during employment and for 18 months thereafter in the case of Mr. Thayer and six months thereafter in the case of Messrs. Earl and Larson), non-solicitation and no-hire of employees and non-solicitation of customers or clients (during employment and for 18 months thereafter in the case of Mr. Thayer and six months thereafter in the case of Messrs. Earl and Larson), confidentiality with respect to Company confidential information (during employment and for five years thereafter), in the case of Messrs. Thayer and Earl only, confidentiality with respect to trade secrets (in perpetuity), assignment of intellectual property and non-disparagement (in perpetuity).

 

244


Table of Contents

Tax and Accounting Considerations

When reviewing compensation matters, we consider the anticipated tax and accounting consequences to us (and, when relevant, to our executive officers) of the various payments under our compensation programs. Section 162(m) of the Internal Revenue Code of 1986, as revised, or the Code, generally limits the tax deductibility of annual compensation paid by public companies for certain executive officers to $1 million. Although we are mindful of the benefits of tax deductibility when determining executive compensation, we may approve compensation that will not be fully-deductible in order to ensure competitive levels of total compensation for our executive officers. We account for stock-based payments, including grants of options under the 2023 Plan, in accordance with the requirements of FASB ASC Topic 718.

Executive Compensation Tables

Summary Compensation Table

The following table sets forth information concerning the compensation paid to our NEOs during our fiscal year ended December 31, 2023.

 

Name and Principal Position

   Year      Salary
($)
     Bonus
($)(1)
     All Other
Compensation
($)(2)
     Total
($)
 

Michael Sabel

     2023        5,584,790        26,000,000        1,997,026        33,581,816  

Chief Executive Officer, Executive Co-Chairman and Founder

              

Jonathan Thayer

     2023        1,500,000        3,875,000        20,150        5,395,150  

Chief Financial Officer

              

Robert Pender

     2023        2,498,252        26,000,000        37,967        28,536,219  

Executive Co-Chairman and Founder

              

Thomas Earl(3)

     2023        1,500,000        4,820,000        37,640        6,357,640  

Chief Commercial Officer

              

Keith Larson

     2023        1,500,000        4,000,000        20,150        5,520,150  

General Counsel and Secretary

              

 

(1)

Amounts reported include (i) a 2023 annual performance bonus in the amount of $25,000,000 for each of Messrs. Sabel and Pender and $2,000,000 for each of Messrs. Thayer, Earl and Larson, (ii) payment of Project Milestone Bonuses equal to $1,000,000 for each of Messrs. Sabel, Thayer and Pender, $1,250,000 for Mr. Earl and $1,125,000 for Mr. Larson; (iii) payment of Strategic Recognition Awards in an amount equal to $875,000 for each of Messrs. Thayer, Earl and Larson; and (iv) for Mr. Earl, Revenue Contract Bonuses equal to $695,000. For additional information on our cash incentive programs, please see “Cash Incentive Compensation Arrangements” above.

(2)

Amount reported includes, as applicable, (i) the value of perquisites and personal benefits (as defined by the SEC), including (A) payments made by the Company on behalf of Mr. Sabel for costs related to personal security at his residences in the amount of $1,840,281, (B) costs related to personal use of the corporate aircraft by Messrs. Sabel and Pender in the amount of $136,595 and $17,817, respectively, and (C) reserved parking allowances in the amount of $350 for each NEO; (ii) 401(k) matching contributions on behalf of our NEOs, other than Mr. Earl, in the amount of $19,800 each; (iii) monthly stipends paid to Mr. Earl for health and welfare benefits in the amount of $36,000 and (iv) contributions to Mr. Earl’s pension in the amount of $1,640. See “—Other Benefits and Perquisites” above for more information. In accordance with applicable SEC rules and requirements, we valued perquisites and personal benefits based on our incremental cost of providing such items.

(3)

All compensation paid to Mr. Earl was earned in U.S. dollars and paid in British pounds using the applicable exchange rates in effect as of the date the compensation is earned. The average daily spot rates of U.S. dollars to British pounds in fiscal year 2023 was 0.8073.

 

245


Table of Contents

Grants of Plan-Based Awards

None of our NEOs received grants of plan-based awards in 2023.

Outstanding Equity Awards at Fiscal-Year End

The following table sets forth information concerning outstanding equity awards for our named executive officers as of the end of our fiscal year ended December 31, 2023. Messrs. Sabel and Pender did not hold any outstanding equity awards as of year-end.

 

Name

  Grant Date(1)     Number of Securities
Underlying

Unexercised
Options (#)

Exercisable
    Number of Securities
Underlying

Unexercised
Options (#)
Unexercisable
    Option Exercise Price
($)
    Option Expiration Date  

Jonathan Thayer

    06/17/2020       4,375       625       5,200       06/17/2030  
    05/12/2022       375       625       15,300       05/12/2032  

Thomas Earl

    07/18/2017       2,000       —        3,568       07/18/2027  
    01/24/2018       1,000       —        3,771       01/24/2028  
    04/01/2019       1,000       —        7,000       04/01/2029  
    04/01/2020       875       125       5,200       04/01/2030  
    04/20/2021       313       187       7,000       04/20/2031  
    05/12/2022       375       625       15,300       05/12/2032  

Keith Larson

    07/01/2017       3,000       —        3,568       07/01/2027  
    01/24/2018       1,000       —        3,771       01/24/2028  
    04/01/2019       2,000       —        7,000       04/01/2029  
    04/20/2021       313       187       7,000       04/20/2031  
    05/12/2022       375       625       15,300       05/12/2032  

 

(1)

All awards granted to our NEOs are options to purchase Series A common shares originally granted under the 2014 Plan which were converted, on a one-for-one basis, in connection with the Reorganization Transactions into options to purchase shares of our Class A common stock under the 2023 Plan and remain outstanding under the 2023 Plan. All options granted to our NEOs vest in equal quarterly installments over a four-year period from the date of grant, subject to the NEO’s continued employment with us through each vesting date.

Option Exercises and Stock Vested

None of our NEOs exercised any stock options during our fiscal year ended December 31, 2023. We do not grant stock awards and, as such, no such awards vested in 2023.

Pension Benefits

None of our NEOs are entitled to any payments or other benefits following or in connection with retirement.

Nonqualified Deferred Compensation

None of our NEOs participate in any plan that provides for the deferral of compensation on a basis that is not tax-qualified.

Potential Payments Upon Termination or Change in Control

The Company does not maintain a formal severance policy, but certain of our NEOs have severance entitlements under the terms of their employment agreements, as described under “Compensation Discussion & Analysis – Executive Employment Agreements” above. As of December 31, 2023, certain of our NEOs were party to offer letters which provided for certain severance entitlements, as described below.

 

246


Table of Contents

The severance provisions under Mr. Thayer’s offer letter are the same as those set forth in his employment agreement. Under Mr. Earl’s offer letter, we or Mr. Earl could terminate his employment at any time with not less than one week notice in writing. In the event Mr. Earl’s employment was terminated by us, we could make a payment in lieu of notice by providing an amount equal to then-current base salary for the remainder of the notice period.

None of our NEOs are entitled to any payments or benefits solely upon a change in control of our Company.

Assuming the termination of employment of Messrs. Thayer and Earl on December 31, 2023 under the circumstances described above, they would have received severance payments in the amount of (i) for Mr. Thayer, $1,500,000 and (ii) for Mr. Earl, $28,846 (assuming payment in lieu of one weeks’ notice of termination).

2023 Stock Option Plan

This section summarizes the key terms of the 2023 Plan as of the date of filing of this registration statement, which was adopted by our Board and approved by our stockholders in September 2023 in connection with the Reorganization Transactions, and amended and restated effective November 14, 2024. As of December 31, 2023, there were stock options outstanding under the 2023 Plan with respect to 67,796 shares of our Class A common stock having a weighted-average exercise price of $6,105.65 per share. In connection with this offering, it is expected that the outstanding stock options and the number of shares available for grant under the 2023 Plan will be equitably adjusted pursuant to a stock split.

Purpose. The purpose of the 2023 Plan is to attract, reward and retain key service providers and to encourage their contribution to the long-term and growth and profitability of the Company.

Eligible Participants. Awards may be made to employees, consultants, service providers, non-employee directors and other individuals whose participation in the 2023 Plan is determined to be in the best interests of the Company.

Authorized Shares. As of November 14, 2024, the maximum number of shares available for issuance under the 2023 Plan was 95,000 shares of Class A common stock (which includes shares of Series A common stock to be issued pursuant to the exercise of options previously granted under the 2014 Plan), plus the shares underlying any awards that are not purchased or are forfeited or expire, or if an award otherwise terminates without delivery of any Class A common stock subject thereto or is settled in cash in lieu of shares. The share capacity will be increased by the number of shares underlying any awards the Company assumes in connection with a merger or other corporate transaction granted under an equity plan of another company. The 2023 Plan’s share capacity may be adjusted if the number of our shares of outstanding common stock increases or decreases or if our shares of common stock are otherwise changed or exchanged in connection with certain capital and corporate transaction.

Administration. The 2023 Plan is administered by a committee of our Board, or the Committee, or if no Committee is designated, the full Board. The Committee has the authority to determine eligible participants, the types of awards to be granted, the number of shares covered by awards and the terms and conditions of awards. The Committee may delegate some or all of its authority with respect to administering the 2023 Plan to our Chief Executive Officer and/or any other officer designated by the Committee, subject to the restrictions in the 2023 Plan.

Award Agreement. Each award granted pursuant to the 2023 Plan will be evidenced by an award agreement which will be in such form or forms as the Committee determines.

Terms and Conditions of Options. The option price of each option will be fixed by the Committee and stated in the award agreement evidencing such option. Except in the case of substitute awards, the exercise price of

 

247


Table of Contents

each option must be at least the fair market value of a share of Class A common stock on the grant date; provided that in the event that a grantee is a 10% Company stockholder, the exercise price of any option intended to be an incentive stock option under Section 422 of the Code is not less than 110% of the fair market value of a share of Class A common stock on the grant date.

Only a grantee (or, in the event of such grantee’s legal incapacity or incompetency, such grantee’s guardian or legal representative) may exercise options granted under the 2023 Plan; provided, however, that if authorized in the applicable award agreement, a grantee may transfer, not for value, all or part of an option which is not an incentive stock option to any family member. Each award agreement will set forth the extent to which a grantee may exercise the granted options following his or her termination of employment.

Incentive Stock Options. The 2023 Plan authorizes the grant of incentive stock options under Section 422 of the Code, subject to those limits specified in the plan and by the Code.

Form of Payment for Options. To the extent provided by the applicable award agreement, the exercise price of options may be paid all or in part through the tender of shares of Class A common stock, which shall be valued at their fair market value on the date of tender.

To the extent permitted by applicable law and the applicable award agreement, an option’s exercise price may be paid all or in part by irrevocably directing a licensed securities broker to sell shares of Class A common stock and to deliver all or part of the proceeds of such sale to us as payment for the options’ exercise price and any withholding taxes, or, with our consent, by net share settlement (i.e., issuing the number of shares equal in value to the difference between the options’ exercise price and the fair market value of the shares subject to the portion of such option being exercised).

Forfeiture. The Committee may reserve the right in an award agreement to cause a forfeiture of the gain realized by a grantee with respect to an award on account of actions taken by, or failed to be taken by, such grantee in violation or breach of any agreement with, or obligation to, the Company.

No Repricing Without Stockholder Approval. Except in connection with certain corporate transactions, (i) the exercise price of an outstanding option may not be reduced; (ii) an outstanding option may not be cancelled or substituted for an option with an exercise price that is less than the exercise price of the original options; or (iii) options with an exercise price above the current Class A common stock price may not be cancelled in exchange for cash or other securities.

Change in Capitalization. If the number of outstanding shares of Class A common stock is increased or decreased, or if the Class A common shares are exchanged for a different number or kind of securities, or in connection with specified capitalization transactions, the number and kinds of share of common stock underlying options granted pursuant to the 2023 Plan shall be adjusted proportionally by the Committee. Any such adjustment will not change the aggregate exercise price of an option award.

Termination of Service. Unless expressly provided otherwise in the applicable award agreement, vested stock options must be exercised within sixty days of an individual’s termination of service with the Company, at which point any unexercised options will be forfeited. The treatment described in this section does not apply to awards made to non-employee directors in their capacity as directors.

Change in Control. Upon a Change in Control (as defined in the 2023 Plan) in which outstanding options are not assumed or continued, the Committee may: (i) cause all options outstanding to be immediately exercisable beginning fifteen days prior to the scheduled consummation of such Change in Control, with such options to remain exercisable for a period of fifteen days, which exercise shall be effective upon such consummation; and/or (ii) elect, in its sole discretion, to cancel any outstanding options and pay or deliver, or cause to be paid or delivered, to the holder thereof an amount in cash or securities with value equal to the number of shares subject to such options multiplied by the amount per share paid to holders of shares pursuant to such

 

248


Table of Contents

transaction exceeds the exercise price applicable to such options. In no event may any option be exercised, in whole or in part, after the occurrence of an event referred to with regard to a Change in Control which results in the termination of such option. Alternatively, option awards may be continued, assumed or substituted in connection with a Change in Control, with appropriate adjustments made to the number of shares underlying the awards and the exercise price.

Term; Amendment and Termination. The 2023 Plan terminates on December 16, 2034. The Board may at any time amend, suspend or terminate the 2023 Plan as to any shares as to which awards have not been made. No amendment, suspension or termination of the 2023 Plan may impair the rights or obligations of any award granted thereunder without the grantee’s consent. We do not expect to make grants under the 2023 Plan following the consummation of the IPO. In connection with this offering, we intend to adopt a new omnibus incentive plan, under which our employees may receive long-term incentive compensation in the future.

Parachute Limitations. The 2023 Plan includes a “best net” provision. If a grantee is a disqualified individual (as defined in Section 280G(c) of the Code), any right of the grantee to any exercise, vesting, payment or benefit under the 2023 Plan should be reduced or eliminated (i) to the extent that any such right to exercise, vesting, payment, or benefit, taking into account all other rights, payments, or benefits to or for the grantee under the plan, would be considered a parachute payment under Section 280G(b)(2) of the Code, and (ii) if as a result of receiving such parachute payment the aggregate after-tax amounts received by the grantee under the 2023 Plan and all other agreements and arrangements would be less than the maximum after-tax amount that could be received by the grantee without causing any such payment or benefit to be considered a parachute payment.

Withholding Taxes. We have the right to deduct from payments of any kind any federal, state or local taxes required by law to be withheld with respect to the vesting of or other lapse of restrictions applicable to an award or upon the issuance of any shares upon the exercise of an option. Subject to our prior approval, a grantee may elect to satisfy such withholding obligation, in whole or in part, (i) by causing us or an affiliate to withhold shares otherwise issuable to the grantee or (ii) by delivering to us or such affiliate shares already owned by the grantee.

U.S. Federal Income Tax Consequences. A non-qualified stock option is an option that does not meet the requirements of Section 422 of the Code. A grantee will not recognize taxable income when granted a non-qualified stock option. When the grantee exercises the stock option, he or she will recognize taxable ordinary income equal to the excess of the fair market value of the shares received on the exercise date over the aggregate exercise price of the shares. The grantee’s tax basis in the shares acquired on exercise of the option will be increased by the amount of such taxable income. We generally will be entitled to a federal income tax deduction in an amount equal to the ordinary income that the grantee recognizes. When the grantee sells the shares acquired on exercise, the grantee will realize long-term or short-term capital gain or loss, depending on whether the grantee holds the shares for more than one year before selling them. Special rules apply if all or a portion of the exercise price is paid in the form of shares.

An incentive stock option is an option that meets the requirements of Section 422 of the Code. A grantee will not have taxable income when granted an incentive stock option or when exercising the option. If the grantee exercises the option and does not dispose of the shares until the later of two years after the grant date and one year after the exercise date, the entire gain, if any, realized when the grantee sells the shares will be taxable as long-term capital gain. We will not be entitled to any corresponding tax deduction.

If a grantee disposes of the shares received upon exercise of an incentive stock option within the one-year or two-year periods described above, it will be considered a “disqualifying disposition,” and the option will be treated as a non-qualified stock option for federal income tax purposes. If a grantee exercises an incentive stock option more than three months after the grantee’s employment or service with us terminates, the option will be treated as a non-qualified stock option for federal income tax purposes. If the grantee is disabled and terminates employment or service because of his or her disability, the three-month period is extended to one year. The three-month period does not apply in the case of the grantee’s death.

 

249


Table of Contents

2024 Omnibus Incentive Plan

We plan to adopt the Omnibus Incentive Plan, which, subject to approval by our Board and our stockholders, will be effective in connection with the completion of this offering. As of the effectiveness of the Omnibus Incentive Plan, all shares that remain available for issuance under our 2023 Plan will become available for issuance under the Omnibus Incentive Plan and no further equity awards will be granted under the 2023 Plan.

Subject to approval by our Board or compensation committee, as applicable, it is anticipated that, in connection with this offering, certain of our non-NEO employees will be granted equity awards under the Omnibus Incentive Plan with respect to     shares of our Class A common stock.

The following summary describes the material terms of the Omnibus Incentive Plan.

Types of Awards. Awards under the Omnibus Incentive Plan include stock options (including options intended to qualify as incentive stock options under Section 422 of the Code, or ISOs, and nonqualified stock options, or NSOs), share appreciation rights, or SARs, restricted stock, restricted stock units, or RSUs, performance awards, other cash-based awards and other share-based awards. We refer to such awards together as “Awards.”

Plan Administration. The Omnibus Incentive Plan will be administered by the compensation committee, unless another committee is designated by the Board. To the extent permitted by applicable law, the compensation committee may delegate some or all of its authority under the Omnibus Incentive Plan, including the authority to grant Awards (other than to participants covered by Section 16 of the Exchange Act), to a subcommittee or subcommittees or to other persons or groups of persons as it deems necessary, appropriate or advisable.

Eligibility. Employees, prospective employees who have accepted an offer of employment, non-employee directors, consultants and any person who has accepted an offer of service or consultancy of the Company or any of its subsidiaries are eligible to be selected to participate in the Omnibus Incentive Plan.

Authorized Shares. Subject to adjustment as described below, the total number of shares of our Class A common stock authorized for issuance under the Omnibus Incentive Plan is      (which number includes shares remaining available for issuance under the 2023 Plan as of the effectiveness of the Omnibus Incentive Plan). The maximum number of shares that may be issued upon the exercise of ISOs under the Omnibus Incentive Plan is      . The number of shares reserved for issuance under the Omnibus Incentive Plan will be increased automatically on the first day of each of fiscal year of our Company following the effective date of the plan by a number equal to the smallest of (i)   % of the number of shares outstanding on the last day of the immediately preceding fiscal year; and (ii) the number of shares determined by the compensation committee in its discretion.

In general, to the extent that any Awards are forfeited, cancelled, expire or otherwise lapses or are settled, in whole or in part, without the issuance of shares, those shares will again become available for issuance under the Omnibus Incentive Plan.

Director Compensation Limit. No non-employee director who participates in the Omnibus Incentive Plan will receive compensation for services on our Board for any calendar year in excess of $     in the aggregate, including cash payments and Awards (which will be calculated based on the grant date fair value for financial reporting purposes), but excluding any awards granted prior to this offering.

Options. The compensation committee is permitted to grant both ISOs and NSOs under the Omnibus Incentive Plan. The exercise price of a stock option may not be less than 100% of the fair market value of a share of our common stock on the grant date (other than in the case of Awards granted in assumption of, or in

 

250


Table of Contents

substitution for, an outstanding award previously granted by a company or other business acquired by the Company or with which the Company combines, which we refer to as “Substitute Awards”). Each option will expire no later than the tenth anniversary of the date the option is granted.

Share Appreciation Rights. The compensation committee is permitted to grant SARs under the Omnibus Incentive Plan. The exercise or hurdle price of a SAR may not be less than 100% of the fair market value of a share of our common stock on the grant date (other than in the case of Substitute Awards). Each SAR will expire no later than the tenth anniversary of the date the SAR is granted.

Restricted Stock and Restricted Stock Units. The compensation committee is permitted to grant restricted stock awards and RSUs under the Omnibus Incentive Plan. A restricted stock award is an award of shares that is subject to restrictions on transfer and a substantial risk of forfeiture. An RSU is an award that is granted with respect to one share or has a value equal to the fair market value of one such share. RSUs may be paid in cash, shares, other Awards, other property or any combination thereof), as determined in the sole discretion of the compensation committee.

Performance Awards. The Omnibus Incentive Plan permits the grant of performance-based stock and/or cash Awards. The compensation committee may structure Awards so that shares, cash, and/or other property will be issued or paid only following the achievement of certain pre-established performance goals during a designated performance period determined by the compensation committee.

Other Cash-Based and Other Share-Based Awards. The compensation committee is permitted to grant other equity or equity-based Awards and cash-based Awards on such terms and conditions as the compensation committee will determine. For Awards in the nature of a purchase right, the purchase price therefore shall not be less than the fair market value of such shares on the date of grant of such right.

Changes in Capitalization. If, as a result of a change affecting the Company or its securities, an adjustment is necessary in order to prevent dilution or enlargement of the benefits or potential benefits intended to be made available under the Omnibus Incentive Plan, the compensation committee will equitably adjust any or all of (i) the number and type of shares (or other securities) which thereafter may be made the subject of Awards under the Omnibus Incentive Plan (including the share limit and the ISO limit) and (ii) the terms of any outstanding Award, including the exercise price, the number or type of shares or other securities of the Company or other property subject to outstanding Awards and/or other terms and conditions of outstanding Awards, including the performance criteria of any performance awards.

Effect of Termination of Service or a Change in Control. The compensation committee may provide, by rule or regulation or in any applicable Award agreement, or may determine in any individual case, an Award may be exercised, settled, vested, paid, repurchased or forfeited in the event of a participant’s termination of service prior to the vesting, exercise or settlement of such Award.

Upon a Change in Control (as defined in the Omnibus Incentive Plan), the compensation committee may take any one or more of the following actions with respect to any outstanding Award (which need not be uniform across Awards or participants): (i) continuation or assumption of Awards by the successor or surviving entity or its parent, (ii) substitution or replacement of Awards by the successor or surviving entity or its parent with cash, securities, rights or other property with substantially the same terms and value as such Awards, (iii) acceleration of the vesting and the lapse of any restrictions either upon termination of service under certain circumstances prior to or following the change in control or upon the failure of the successor or surviving entity to continue to assume such Awards, (iv) in the case of a performance Award, the determination of the level of attainment of the applicable performance condition(s), and (v) cancellation of such Award in consideration of a payment in cash, securities or other property or, in certain circumstances, for no consideration.

Awards granted under the Omnibus Incentive Plan may be subject to acceleration of vesting and exercisability upon or after a change in control as may be provided in the applicable Award agreement or in any other written agreement between the Company or any of its subsidiaries and the participant.

 

251


Table of Contents

Clawback. Under the Omnibus Incentive Plan, Awards (including any amounts or benefits arising from such Awards) will be subject to any clawback or recoupment arrangements or policies the Company has in place from time to time, and the compensation committee may, to the extent permitted by applicable law and stock exchange rules or by any applicable Company policy or arrangement, and will, to the extent required, cancel or require reimbursement of any Awards or any shares issued or cash received upon vesting, exercise or settlement of any such Awards or sale of shares underlying such Awards, including any policies necessary to comply with Section 10D of the Exchange Act and any rules promulgated thereunder and any other regulatory regimes.

No Repricing Without Stockholder Approval. Except in connection with changes in capitalization (as described above) or with the approval of the Company’s stockholders, (i) the exercise price of an outstanding option may not be reduced; (ii) an outstanding option may not be cancelled or substituted for an option with an exercise price that is less than the exercise price of the original options; or (iii) options with an exercise price above the current share price may not be cancelled in exchange for cash or other securities.

Amendment. Except to the extent prohibited by applicable law and unless otherwise expressly provided in an Award agreement or in the Omnibus Incentive Plan, our Board may amend, alter, suspend, discontinue or terminate the Omnibus Incentive Plan or any portion thereof at any time; provided that no such amendment, alternation, suspension, discontinuation or termination shall be made without (i) stockholder approval if such approval is required by applicable law or the rules of the stock market or exchange on which the shares are principally quoted or trade, or (ii) subject to limitations, the consent of the affected participant of the Omnibus Incentive Plan if such action would materially adversely affect the rights of such participant under any outstanding Award.

Term. The Omnibus Incentive Plan will become effective on the date on which the registration statement covering this offering is declared effective by the Securities and Exchange Commission. No Award may be granted under the Omnibus Incentive Plan after the earliest of (i) the tenth anniversary of the effective date, (ii) the maximum number of shares of our Class A common stock available for issuance under the Omnibus Incentive Plan have been issued or (iii) the Board terminates the Omnibus Incentive Plan. Previously granted Awards are permitted to extend beyond the termination date of the Omnibus Incentive Plan.

Director Compensation

The following table sets forth information concerning the compensation earned by each of our non-employee directors during the fiscal year ended December 31, 2023.

 

Name (1)

   Fees Earned or Paid in
Cash

($)
     Option Awards
($)(3)
     Total
($)
 

Roderick Christie(2)

   $ 180,000      $ 4,097,061      $ 4,277,061  

Sari Granat

   $ 220,000        —       $ 220,000  

Andrew Orekar

   $ 220,000        —       $ 220,000  

Thomas J. Reid

   $ 200,000        —       $ 200,000  

Jimmy Staton

   $ 220,000        —       $ 220,000  

 

(1)

Roderick Christie was appointed to our Board on June 1, 2023.

(2)

Meeting fees reported with respect to Mr. Christie were earned in U.S. dollars and paid in British pounds using exchange ratios of 0.7871, 0.8030 and 0.7942, which represent the Oanda exchange rates in effect as of June 16, 2023, September 15, 2023 and December 7, 2023, the dates of the applicable board meetings for which such fees were earned and paid.

(3)

The amounts reported in this column represent the aggregate grant date fair value of the option awards granted to our non-employee directors during 2023, as calculated in accordance with FASB Accounting Standards Codification Topic 718. The assumptions used in calculating the grant date fair value of the options in this column are described in Note 19 to our consolidated financial statements included elsewhere in this prospectus. The aggregate number of option awards outstanding for each of our non-employee

 

252


Table of Contents
  directors as of December 31, 2023 was: Mr. Christie, 500 options; Ms. Granat, 500 options; Mr. Orekar, 500 options; Mr. Reid, 500 options; and Mr. Staton, 4,416 options (2,916 of which were awarded in connection with Mr. Staton’s service as an employee of the Company).

Prior to this offering, each of our non-employee directors received a fee of $60,000 (increased from $20,000 effective as of June 1, 2023) payable in cash for each regular and special Board meeting attended, whether in person or by telephone. In addition, each of our non-employee directors received a grant of stock options in connection with their appointment to our Board, which options vest in equal quarterly installments over a four-year period from the grant date, subject to their continued service through each vesting date (other than the 2,916 options awarded to Mr. Staton in connection with his service as an employee of the Company, which vest in equal quarterly installments over a three-year period). Our non-employee directors are reimbursed for their reasonable expenses incurred in attending meetings of the Board or committees. Employee directors do not receive additional compensation for their service on the Board.

In connection with this offering, we intend to adopt, subject to approval by our Board, a director compensation policy which will govern the annual compensation paid to our non-employee directors following this offering. Our non-employee director compensation policy will be administered by our compensation committee and will provide each of our non-employee directors with an annual cash retainer for service on the Board of $   , plus additional cash retainers for service as the chair of a committee of the Board or a member of a committee of the Board, as follows: (i) Audit Committee Chair - $   ; (ii) Audit Committee member - $   ; (iii) Compensation Committee Chair - $   ; (iv) Compensation Committee member - $   ; (v) Nominating and Governance Committee Chair - $   ; and (vi) Nominating and Governance Committee member - $   . In addition, non-employee directors will receive (i) an equity grant made upon initial election or appointment to our Board with a grant date value of $    and (ii) annual grants with a grant date value of $   , to be made on or about the date of our annual stockholder meeting.

 

253


Table of Contents

CERTAIN RELATIONSHIPS AND RELATED PARTY TRANSACTIONS

We describe below transactions and series of similar transactions, during our last three fiscal years or currently proposed, to which we were a party or will be a party, in which:

 

   

the amounts involved exceeded or will exceed $120,000; and

 

   

any of our directors, executive officers or beneficial holders of more than 5% of any class of our capital stock had or will have a direct or indirect material interest.

Other than as described below, there have not been, nor are there any currently proposed, transactions or series of similar transactions meeting this criteria to which we have been or will be a party other than compensation arrangements, which are described where required under “Management—Board Structure and Compensation of Directors” and “Executive Compensation.”

Reorganization Transactions

In connection with certain reorganization transactions, or the Reorganization Transactions, Legacy VG Partners, the Company and certain entities affiliated with Pacific Investment Management Company, or PIMCO, holding VGLNG’s Series C common stock entered into a transaction agreement on September 25, 2023, or the Transaction Agreement. Pursuant to the Transaction Agreement, the Company issued 78,464 shares of Class A common stock to PIMCO, in exchange for all of PIMCO’s outstanding 78,464 shares of Series C common stock in VGLNG. In addition, Legacy VG Partners agreed to merge with and into the Company, with VG Partners receiving 435,499 shares of Class A common stock in the Company in exchange for its equity interests in Legacy VG Partners. Moreover, VG Partners received one Class A common in the Company stock in exchange for its one share of Series A common stock of VGLNG.

In addition, in connection with the Reorganization Transactions, the remaining shareholders of VGLNG, which consisted of certain shareholders holding 5,808 shares of VGLNG’s Class C common shares that were not party to the Transaction Agreement, received 5,808 Class A common stock of the Company in exchange for such Series C common shares.

As a result, VGLNG, our principal operating company, became a direct, wholly-owned subsidiary of the Company. Additionally, VG Commodities, formerly a wholly-owned subsidiary of Legacy VG Partners, became a wholly-owned subsidiary of the Company and a direct, wholly owned subsidiary of VGLNG. After giving effect to the Reorganization Transactions, VG Partners, the controlling shareholder of the Company, owns approximately 84% of the issued and outstanding shares of Class A common stock, which shares automatically convert into shares of Class B common stock of the Company, which have 10 votes per Class B common stock, immediately prior to the consummation of the first underwritten initial public offering of Class A common stock, so long as such shares are held by VG Partners, its affiliates or other related parties at such time.

Existing Shareholders’ Agreement

In connection with the Reorganization Transactions, the Company and all of the holders of its outstanding common stock immediately prior to consummation of the offering, or, collectively, the Pre-IPO Stockholders, entered into the Shareholders’ Agreement, dated as of September 25, 2023, or the Existing Shareholders’ Agreement, governing the ownership of the shares of the Company. The Existing Shareholders’ Agreement contains certain consent rights for certain actions or decisions as well as registration rights and tag-along rights with respect to certain offerings and dispositions of stock of the Company.

Effective upon the consummation of this offering, all provisions of the Existing Shareholders’ Agreement will automatically terminate, except for certain registration rights, which will be reflected in an amended and restated version of the Existing Shareholders’ Agreement, or the Amended and Restated Shareholders’ Agreement.

 

254


Table of Contents

Amended and Restated Shareholders’ Agreement

Pursuant to the Amended and Restated Shareholders’ Agreement, our Pre-IPO Stockholders will be entitled to certain demand and piggyback registration rights with respect to their shares of our common stock. The Pre-IPO Stockholders will hold an aggregate of   shares of our Class A common stock and   shares of our Class B common stock, or approximately   % of the total combined voting power of our common stock outstanding upon the completion of this offering (or   % if the underwriters exercise their option to purchase additional shares from us in full). The registration rights described below will terminate with respect to any registrable securities upon the occurrence of certain events, including if sold pursuant to Rule 144 promulgated under the Securities Act or an effective registration statement under the Securities Act, or if such registrable securities are eligible to be sold under Rule 144 promulgated under the Securities Act and the Pre-IPO Stockholders no longer beneficially own in the aggregate common stock equal to at least 10% of our then outstanding common stock, in each case subject to certain conditions. Upon transfer of any shares of registrable securities to any person (other than an affiliate of the transferee) in accordance with the terms of the Amended and Restated Shareholders’ Agreement, such shares will cease to be “registrable securities” and will no longer have the benefit of the Amended and Restated Shareholders’ Agreement.

Piggyback Registration Rights. Subject to certain exclusions, in the event that we register any of our equity securities under the Securities Act after this offering, the Pre-IPO Stockholders will be entitled to certain piggyback registration rights allowing each to include its shares of Class A common stock in the registration, subject to certain marketing and other limitations. If any managing underwriter advises that marketing factors require a limitation of the number of shares to be included in any registration, then the number of shares to be included in such registration will be allocated pro rata based on the number of shares requested to be included in the registration by the initiating security holders and any such Pre-IPO Stockholders exercising piggyback registration rights. As a result, whenever we propose to file a registration statement under the Securities Act for the account of any of our security holders under the Amended and Restated Shareholders’ Agreement, Pre-IPO Stockholders will be entitled to notice of the registration.

Demand Registration Rights. At any time beginning 180 days after the completion of this offering, any Pre-IPO Stockholders holding at least 5% of our then outstanding common stock may request that we register, either by filing a Form S-1 registration statement or, if eligible, a Form S-3 registration statement, all or a portion of their Class A common stock. Any such request must cover a quantity of shares with an anticipated aggregate offering price, net of underwriting discounts and commissions, of at least $100.0 million. To the extent applicable, any of the Pre-IPO Stockholders holding at least 5% of our then outstanding common stock may then request an underwritten offering or block trade using any existing and effective shelf registration statement, in each case subject to certain conditions. Depending on certain conditions, we may defer a demand registration for up to 120 days after receiving the request of the initiating holders; provided that we may not invoke this right more than twice in any twelve-month period.

Public Offering Lock-up. In connection with any underwritten public offering, the Pre-IPO Stockholders agree to not transfer or dispose of their Class A common stock for 180 days from the date of the final prospectus (in the case of this offering) or 90 days or such shorter period as may be agreed to by the managing underwriters (in the case of any other public offering), in each case, subject to certain exceptions, except with the prior written consent of the applicable managing underwriters of the applicable public offering.

Expenses; Indemnification. The registration rights of the Pre-IPO Stockholders under the Amended and Restated Shareholders’ Agreement will provide that we must pay all registration expenses (other than the underwriting discounts and commissions) in connection with effecting any demand registration or shelf registration, and contains customary indemnification and contribution provisions.

Management Services Agreements

VGLNG Management Services Agreement

VGLNG entered into a management services agreement with Legacy VG Partners on June 27, 2014, which we subsequently amended and restated in December 2014 and April 2015, or, as amended, the VGLNG

 

255


Table of Contents

Management Services Agreement. In connection with the Reorganization Transactions, Legacy VG Partners was merged with and into the Company and the VGLNG Management Services Agreement was assigned from Legacy VG Partners to VG Partners, effective as of September 25, 2023.

Pursuant to the VGLNG Management Services Agreement, VG Partners is required to provide strategic advice in the form of such management services to VGLNG as VGLNG may request from time to time with respect to the Calcasieu Project, the Plaquemines Project and any other LNG facilities that VGLNG develops. The term of the VGLNG Management Services Agreement commenced on December 1, 2014, and continues until the later of either (i) the expiration of the useful life of all of the LNG projects that VGLNG develops, or (ii) 25 years after COD of the last LNG project VGLNG develops that achieves commercial operations, subject to extension thereafter.

Since August 2019, VGLNG has been required to pay Legacy VG Partners or VG Partners, as applicable, a fee for its availability to perform the services pursuant to the VGLNG Management Services Agreement . Such fee is $500,000 per month (increased annually for inflation based on the consumer price index). Pursuant to the VGLNG Management Services Agreement, VGLNG incurred fees payable to Legacy VG Partners of $6.4 million and $6.1 million, for the years ended December 31, 2022 and 2021, respectively. For the year ended December 31, 2023, VGLNG incurred fees payable to Legacy VG Partners of $5 million, and fees payable to VG Partners of $2 million under such agreement.

Venture Global Management Services Agreement

VG Commodities entered into a management services agreement, or the Venture Global Management Services Agreement, with Legacy VG Partners on December 1, 2014. In connection with the Reorganization Transactions, the Venture Global Management Services Agreement was assigned from Legacy VG Partners to VG Partners and from VG Commodities to the Company, effective as of September 25, 2023.

Pursuant to the Venture Global Management Services Agreement, VG Partners is required to provide strategic advice in the form of such management services to us as we may request from time to time, including with respect to the optimization of the purchase and sale of excess capacity from VGLNG’s projects and related agreements. The term of the Venture Global Management Services Agreement commenced on December 1, 2014, and continues until the later of either (i) the expiration of the useful life of all of the LNG projects that VGLNG develops, or (ii) 25 years after COD of the last LNG project VGLNG develops that achieves commercial operations, subject to extension thereafter. Upon the occurrence of the Calcasieu Project’s COD, we will be required to pay VG Partners $500,000 per month (increased annually for inflation based on the consumer price index) pursuant to the VGLNG Management Services Agreement.

As of December 31, 2023, no fees have been paid under the Venture Global Management Services Agreement.

Limitation of Liability and Indemnification of Directors and Officers

Our amended and restated certificate of incorporation and our amended and restated bylaws, as these documents will be in effect following the completion of this offering, will contain provisions that limit the liability of our directors or officers for monetary damages to the fullest extent permitted by Delaware law. See “Description of Capital Stock—Limitation of Liability and Indemnification of Directors and Officers.”

Further, prior to the completion of this offering, we expect to enter into indemnification agreements with each of our directors and officers that may be broader than the specific indemnification provisions contained in the DGCL. These indemnification agreements will require us, among other things, to indemnify our directors and officers against liabilities that may arise by reason of their status or service. These indemnification agreements will also require us to advance all expenses incurred by the directors and officers in investigating or defending any such action, suit, or proceeding. We believe that these charter and bylaw provisions and indemnification agreements are necessary to attract and retain qualified individuals to serve as directors and officers.

 

256


Table of Contents

Policies and Procedures for Related Person Transactions

Our board of directors intends to adopt a written related person transaction policy, to be effective upon the closing of this offering, setting forth the policies and procedures for the review and approval or ratification of related person transactions. This policy will cover, with certain exceptions set forth in Item 404 of Regulation S-K under the Securities Act, any transaction, arrangement or relationship, or any series of similar transactions, arrangements or relationships, in which we were or are to be a participant, where the amount involved exceeds $120,000 in any fiscal year and a related person had, has or will have a direct or indirect material interest, including without limitation, purchases of goods or services by or from the related person or entities in which the related person has a material interest, indebtedness, guarantees of indebtedness and employment by us of a related person. In reviewing and approving any such transactions, we consider all relevant facts and circumstances, including, but not limited to, whether the transaction is on terms comparable to those that could be obtained in an arm’s length transaction and the extent of the related person’s interest in the transaction. All of the transactions described in this section occurred prior to the adoption of this policy. However, the policy will apply to new agreements, amendments and modifications to existing agreements, terminations, disputes and extensions, in each case involving amounts in excess of $120,000.

 

257


Table of Contents

PRINCIPAL STOCKHOLDERS

The following table sets forth information regarding beneficial ownership of our common stock as of    , 2024 by:

 

   

each person, or group of affiliated persons, known by us to beneficially own more than 5% of our common stock;

 

   

each of the directors and named executive officers individually; and

 

   

all directors and executive officers as a group.

We have determined beneficial ownership in accordance with the rules and regulations of the SEC, and the information is not necessarily indicative of beneficial ownership for any other purpose. Except as indicated by the footnotes below, we believe, based on information furnished to us, that the persons and entities named in the table below have sole voting and sole investment power with respect to all shares that they beneficially own, subject to applicable community property laws.

Applicable number of shares beneficially owned and the percentage ownership before this offering is based on   shares of our Class A common stock and shares of our Class B common stock outstanding as of    , 2024, and gives effect to the Stock Split and the automatic conversion of all shares of Class A common stock held immediately prior to the completion of this offering by VG Partners into     shares of our Class B common stock, which will occur immediately after the Stock Split and immediately prior to the completion of this offering, in each case, as if such Stock Split and automatic conversion occurred as of , 2024. Applicable percentage ownership after this offering if the underwriters’ option to purchase additional shares to cover over-allotments, if any, is not exercised is based on (1)     shares of Class A common stock and (2)     shares of Class B common stock outstanding immediately after the closing of this offering. Applicable percentage ownership after this offering if the underwriters’ option to purchase additional shares to cover over-allotments, if any, is exercised in full is based on (1)     shares of Class A common stock and (2)     shares of Class B common stock outstanding immediately after the closing of this offering. Applicable number of shares beneficially owned and the percentage ownership after this offering also excludes any potential purchases in this offering by the persons and entities named in the table below.

In computing the number of shares beneficially owned by a person and the percentage ownership of such person, we deemed to be outstanding all shares issuable pursuant to stock options that are exercisable within 60 days of    , 2024. However, except as described above, we did not deem such shares outstanding for the purpose of computing the percentage ownership of any other person.

Unless otherwise indicated, the address for each listed stockholder is: c/o Venture Global, Inc., 1001 19th Street North, Suite 1500, Arlington, VA, 22209. To our knowledge, except as indicated in the footnotes to this table and pursuant to applicable community property laws, the persons named in the table have sole voting and investment power with respect to all shares of common stock.

 

258


Table of Contents
    Beneficial Ownership
Before the Offering(1)
    % of
Total
Voting
Power
Before
the
Offering

(2)
    Beneficial Ownership
After the Offering if
Underwriters’ Option is
Not Exercised(1)
    % of
Total
Voting
Power
After
the
Offering

(2)
    Beneficial Ownership
After the Offering if
Underwriters’ Option is

Exercised in Full(1)
       
    Class A
Common Stock
    Class B
Common Stock
    Class A
Common Stock
    Class B
Common Stock
    Class A
Common Stock
    Class B
Common Stock
    % of
Total
Voting
Power
After
the
Offering

(2)
 
Name of Beneficial Owner   Shares     %     Shares     %     Shares     %     Shares     %     Shares     %     Shares     %  

5% Stockholders:

                             

Venture Global Partners II, LLC(3)

                             

Directors and Named Executive Officers:

                             

Michael Sabel

                             

Robert Pender

                             

Sari Granat

                             

Andrew Orekar

                             

Thomas J. Reid

                             

Jimmy Staton

                             

Roderick Christie

                             

Jonathan Thayer

                             

Keith Larson

                             

Thomas Earl

                             

All directors and executive officers as a group (12 persons)

                             

 

*

Represents less than 1%.

(1)

After giving effect to the Stock Split and the automatic conversion of all shares of Class A common stock held immediately prior to the completion of this offering by VG Partners into     shares of our Class B common stock, which will occur immediately after the Stock Split and immediately prior to the completion of this offering.

(2)

Percentage of total voting power represents voting power with respect to all shares of our Class A common stock and Class B common stock, as a single class. The holders of our Class B common stock are entitled to ten votes per share, and holders of our Class A common stock are entitled to one vote per share. For more information about the voting rights of our Class A and Class B common stock, see “Description of Capital Stock—Common Stock.”

(3)

Robert Pender and Michael Sabel are managing partners of Venture Global Partners II, LLC, and as such, are deemed to have voting and dispositive power over the common stock held by Venture Global Partners II, LLC. The address for Venture Global Partners II, LLC is 1001 19th Street North, Suite 600, Arlington, VA 22209.

 

259


Table of Contents

DESCRIPTION OF CAPITAL STOCK

The following information reflects our amended and restated certificate of incorporation and amended and restated bylaws as these documents will be in effect following the completion of this offering. The following descriptions are summaries of the material terms of these documents and relevant sections of the DGCL. Reference is made to the more detailed provisions of, and the descriptions are qualified in their entirety by reference to, these documents, copies of which are filed with the SEC as exhibits to the registration statement of which this prospectus is a part, and applicable law.

General

Following this offering, our authorized capital stock will consist of   shares of Class A common stock, par value $0.01 per share,   shares of Class B common stock, par value $0.01 per share, and   shares of preferred stock, par value $0.01 per share.

Common Stock

Common stock outstanding

Prior to this offering (but after giving effect to the Stock Split), there will be    shares of Class A common stock outstanding, held of record by twelve stockholders and no shares of Class B common stock outstanding. Immediately following consummation of this offering, there will be   shares of Class A common stock outstanding and   shares of Class B common stock outstanding, assuming no exercise of the underwriters’ option to purchase additional shares and no exercise of outstanding options and after giving effect to the sale of the shares of Class A common stock offered hereby and the conversion of all Class A common stock held by VG Partners (immediately after the Stock Split and prior to completion of this offering) into shares of Class B common stock. All outstanding shares of common stock are fully paid and non-assessable, and the shares of common stock to be issued upon completion of this offering will be fully paid and non-assessable.

Except as otherwise expressly provided in our amended and restated certificate of incorporation or as required by applicable law and as described herein, our Class A common stock and Class B common stock have the same rights, are equal in all respects and are treated by us as if they were the same.

Stock Split

In accordance with the DGCL, after the effectiveness of the registration statement of which this prospectus forms a part and before the completion of this offering, a  -for-1 forward stock split of our Class A common stock will be effected, whereby each one share of our Class A common stock held in treasury or issued and outstanding will automatically and without any further action by the holder thereof or us, be subdivided into    shares of Class A common stock.

Voting rights

Shares of our Class A common stock are entitled to one vote per share and shares of our Class B common stock are entitled to ten votes per share. Our shares of Class B common stock will convert automatically into one fully paid and nonassessable share of Class A common stock upon any transfer of such share, except for certain permitted transfers described in our amended and restated certificate of incorporation. See “—Conversion, Exchange and Transferability.” Holders of shares of Class A common stock and Class B common stock will vote together as a single class on all matters (including the election of directors) submitted to a vote of stockholders, except as otherwise required by applicable law or as set forth in our amended and restated certificate of incorporation.

 

260


Table of Contents

Conversion, Exchange and Transferability

Shares of Class A common stock are not convertible into any other class of shares.

Each outstanding share of Class B common stock may at any time, at the option of the holder, be converted into one fully paid and nonassessable share of Class A common stock. In addition, each outstanding share of Class B common stock will be automatically converted into one share of Class A common stock upon any transfer of such share of Class B common stock, except for certain permitted transfers described in our amended and restated certificate of incorporation. Permitted transferees include VG Partners, its affiliates and beneficial owners and their beneficial owners’ immediate family members and estate planning vehicles.

Other than as described above, our Class B common stock will not be converted into Class A common stock.

Dividend rights

Subject to preferences that may be applicable to any outstanding preferred stock, the holders of common stock are entitled to receive ratably such dividends, if any, as may be declared from time to time by the board of directors out of funds legally available therefor. See “Dividend Policy.”

We will not declare or pay any dividend to the holders of shares of our common stock unless it is made ratably on an equal priority, pari passu basis among the holders of our common stock as a single class; provided, however, that (i) dividends payable in shares of Class A common stock (or rights to acquire, or securities convertible into or exchangeable for, such shares, as the case may be) may be declared and paid to the holders of Class A common stock without the same dividend being declared and paid to the holders of Class B common stock if, and only if, a dividend payable in shares of Class B common stock (or rights to acquire, or securities convertible into or exchangeable for, such shares, as the case may be), are declared and paid to the holders of Class B common stock at the same rate and with the same record date and payment date, (ii) dividends payable in shares of Class B common stock (or rights to acquire, or securities convertible into or exchangeable for, such shares, as the case may be) may be declared and paid to the holders of Class B common stock without the same dividend being declared and paid to the holders of Class A common stock if, and only if, a dividend payable in shares of Class A common stock (or rights to acquire, or securities convertible into or exchangeable for, such shares, as the case may be) are declared and paid to the holders of Class A common stock at the same rate and with the same record date and payment date and (iii) dividends payable in shares of any other class or series of securities, including our securities or the securities of any other person (or rights to acquire, or securities convertible into or exchangeable for, such shares, as the case may be) may be declared and paid to the holders of shares of our common stock on a different or disproportionate basis if the only differences are in voting power and such other differences that are substantially equivalent (as determined by our board of directors) to the relative designations, preferences, qualifications, privileges, limitations, restrictions and rights.

Furthermore, our board of directors may pay a different or disproportionate dividend per share of our Class A common stock or Class B common stock (whether in the amount of such dividend payable per share, the form in which such dividend is payable, the timing of the payment, or otherwise) that would otherwise be prohibited by the immediately preceding sentence, if such different or disproportionate dividend is approved by the affirmative vote of the holders of a majority of the voting power of the outstanding shares of our Class A common stock and Class B common stock, each voting as a separate class.

Rights upon liquidation

In the event of our liquidation, dissolution or winding up, the holders of common stock are entitled to share ratably in all assets remaining after payment of liabilities, subject to prior distribution rights of preferred stock, if any, then outstanding.

 

261


Table of Contents

Other rights

Other than as described above, holders of our common stock have no preemptive or conversion rights or other subscription rights. There are no redemption or sinking fund provisions applicable to the common stock.

Registration Rights

Under the Amended and Restated Shareholders’ Agreement, the holders of   shares of our Class A common stock and    shares of our Class B common stock will have the right to require us to register the offer and sale of such shares of Class A common stock and shares of Class A common stock into which such Class B common stock is convertible, as applicable, which we refer to as registration rights. See “Certain Relationships and Related Party Transactions—Amended and Restated Shareholders’ Agreement.”

Preferred Stock

Our board of directors has the authority to issue the preferred stock in one or more series and to fix the rights, preferences, privileges and restrictions thereof, including dividend rights, dividend rates, conversion rights, voting rights, terms of redemption, redemption prices, liquidation preferences and the number of shares constituting any series or the designation of such series, without further vote or action by the stockholders.

The issuance of preferred stock may have the effect of delaying, deferring or preventing a change in control of us without further action by the stockholders and may adversely affect the voting and other rights of the holders of common stock. At present, we have no plans to issue any of the preferred stock.

Annual Stockholders Meeting

Our amended and restated certificate of incorporation provides that the annual meeting of stockholders shall be held in the manner designated by the board of directors each year, at which meeting, directors shall be elected and any other proper business may be transacted.

Election and Removal of Directors

Our board of directors will initially consist of between three and eleven directors, and the number of directors may be changed only by resolution of the board of directors; provided, however, that prior to the Trigger Date our stockholders may also fix the number of directors. Any vacancy occurring on the board of directors and any newly created directorship may be filled only by a majority of the remaining directors in office, even if less than a quorum, by a sole remaining director or by the stockholders; provided that after the Trigger Date, any vacancy occurring on the board of directors and any newly created directorship may only be filled by a majority of the directors then in office, even if less than a quorum, or by a sole remaining director (and not by the shareholders).

Our directors may be removed by our stockholders only for cause and with the affirmative vote of holders of at least 75% of the combined voting power of our then-outstanding common stock; provided, however, that prior to the Trigger Date, directors may be removed with or without cause by an affirmative vote of a majority of the combined voting power of our common stock.

Anti-Takeover Effects of our Certificate of Incorporation and By-laws

Some provisions of our amended and restated certificate of incorporation and bylaws are designed to discourage coercive takeover practices and inadequate takeover bids. These provisions are also designed to encourage persons seeking to acquire control of us to first negotiate with our board of directors. We believe that the benefits of increased protection give us the potential ability to negotiate with the proponent of an unfriendly or unsolicited proposal to acquire or restructure us, and that the benefits of this increased protection outweigh the disadvantages of discouraging those proposals, because negotiation of those proposals could result in an improvement of their terms.

 

262


Table of Contents

Classified Board of Directors

Our board of directors will initially consist of a single class of directors serving one year terms, and at each annual meeting of stockholders, directors will be elected to succeed the class of directors whose terms have expired. However, at any time after the Trigger Date, our board of directors will be divided into three classes of directors, with each class as equal in number as possible, serving staggered three-year terms, other than directors who may be elected by holders of preferred stock, if any. The classification of our board of directors into three classes could have the effect of increasing the length of time necessary to change the composition of a majority of the board of directors. In general, at least two annual meetings of stockholders will be necessary for stockholders to effect a change in a majority of the members of the board of directors.

Limits on Written Consents

After the Trigger Date, our amended and restated certificate of incorporation provides that holders of our common stock will not be able to act by written consent without a meeting, unless such consent is unanimous. Prior to such time, shareholder actions may be taken by written consent without a meeting.

Stockholder Meetings

After the Trigger Date, our amended and restated certificate of incorporation provides that special meetings of our stockholders may be called only by a majority of the directors, our chief executive officer, chairman or co-chairman of our board of directors, and by no other person. Prior to such time, a special meeting of stockholders may also be called by stockholders holding a majority of the outstanding shares entitled to vote.

Amendment of Certificate of Incorporation

Our amended and restated certificate of incorporation generally may be amended by the affirmative vote of shares representing a majority of the shares then entitled to vote; provided, however, that after the Trigger Date, certain provisions of our amended and restated certificate of incorporation including but not limited to those described under “—Classified Board of Directors,” “—Limits on Written Consents,” “—Stockholder Meetings,” “—Amendment of Bylaws,” “—Delaware Anti-Takeover Law,” “Limitation of Liability and Indemnification of Directors and Officers,” “Forum Selection” and those sections under “Common Stock” titled “Voting Rights,” “Conversion, Exchange and Transferability,” “Dividend Rights,” “Rights Upon Liquidation,” and “Other Rights” may be amended only by the affirmative vote of holders of at least 75% of the total combined voting power of our shares of voting stock, voting together as a single class.

Amendment of Bylaws

After the Trigger Date, our amended and restated bylaws may generally be altered, amended or repealed, and new bylaws may be adopted, with:

 

   

the affirmative vote of a majority of directors present at any regular or special meeting of the board of directors called for that purpose; or

 

   

the affirmative vote of holders of 75% of the total combined voting power of our outstanding share of voting stock, voting together as a single class.

Prior to such time, our amended and restated bylaws may be amended by either the affirmative vote of a majority of directors present at any regular or special meeting of the board of directors called for that purpose, or the affirmative vote of shares representing a majority of the shares then entitled to vote.

Stockholders Advance Notice Procedures

Our amended and restated bylaws will provide advance notice procedures for stockholders seeking to bring business before annual or special meetings of stockholders or to nominate candidates for election as directors at

 

263


Table of Contents

annual or special meetings of stockholders. Our amended and restated bylaws will also specify certain requirements regarding the form and content of a stockholder’s notice. These provisions might preclude our stockholders from bringing matters before annual or special meetings of stockholders or from making nominations for directors at annual or special meetings of stockholders if the proper procedures are not followed. We expect that these provisions may also discourage or deter a potential acquirer from conducting a solicitation of proxies to elect the acquirer’s own slate of directors or otherwise attempting to obtain control of our company.

Notwithstanding the foregoing, at any time when VG Partners and its permitted transferees beneficially own, in the aggregate, at least 5% of the total combined voting power of our common stock, such advance notice procedure will not apply to VG Partners.

Delaware Anti-Takeover Law

We have expressly elected not to be governed by the “Business Combination” provisions of Section 203 of the DGCL until the earlier of the time (i) at which VG Partners and its permitted transferees no longer beneficially own at least 15% of the combined voting power of our then-outstanding common stock and (ii) our board of directors determines that we will be subject to Section 203 of the DGCL and gives written notice to VG Partners that VG Partners and its permitted transferees shall not be subject to Section 203 of the DGCL. Section 203 prevents an “interested stockholder,” which is defined generally as a person owning 15% or more of a corporation’s voting stock, or any affiliate or associate of that person, from engaging in a broad range of “business combinations” with the corporation for three years after becoming an interested stockholder unless:

 

   

the board of directors of the corporation had previously approved either the business combination or the transaction that resulted in the stockholder’s becoming an interested stockholder;

 

   

upon completion of the transaction that resulted in the stockholder’s becoming an interested stockholder, that person owned at least 85% of the voting stock of the corporation outstanding at the time the transaction commenced, other than statutorily excluded shares; or

 

   

following the transaction in which that person became an interested stockholder, the business combination is approved by the board of directors of the corporation and holders of at least two-thirds of the outstanding voting stock not owned by the interested stockholder.

Under Section 203, the restrictions described above also do not apply to specific business combinations proposed by an interested stockholder following the announcement or notification of designated extraordinary transactions involving the corporation and a person who had not been an interested stockholder during the previous three years or who became an interested stockholder with the approval of a majority of the corporation’s directors, if such extraordinary transaction is approved or not opposed by a majority of the directors who were directors prior to any person becoming an interested stockholder during the previous three years or were recommended for election or elected to succeed such directors by a majority of such directors.

Section 203 may make it more difficult for a person who would be an interested stockholder to effect various business combinations with a corporation for a three-year period. Section 203 also may have the effect of preventing changes in our management and could make it more difficult to accomplish transactions which our stockholders may otherwise deem to be in their best interests.

Limitation of Liability and Indemnification of Directors and Officers

Our amended and restated certificate of incorporation and our amended and restated bylaws will provide that no director or officer will be personally liable to us or our stockholders for monetary damages for breach of fiduciary duty as a director or officer, except as required by applicable Delaware law, as in effect from time to time. Currently, Delaware law requires that liability be imposed for the following:

 

   

any breach of the director’s or officer’s duty of loyalty to us or our stockholders;

 

264


Table of Contents
   

any act or omission of a director or officer not in good faith or which involved intentional misconduct or a knowing violation of law;

 

   

with respect to a director, unlawful payment of dividends or unlawful stock repurchases or redemptions as provided in Section 174 of the DGCL;

 

   

any transaction from which the director derived an improper personal benefit; and

 

   

with respect to an officer, any action by or in our right.

As a result, neither we nor our stockholders have the right, through stockholders’ derivative suits on our behalf, to recover monetary damages against a director for breach of fiduciary duty as a director, including breaches resulting from grossly negligent behavior, except in the situations described above.

Our amended and restated certificate of incorporation will provide that, to the fullest extent permitted by Delaware law, we will indemnify our officers or directors against all damages, claims and liabilities arising out of the fact that the person is or was our director or officer, or served any other enterprise at our request as a director, officer, employee, agent or fiduciary. We will reimburse the expenses, including attorneys’ fees, incurred by a person indemnified by this provision when we receive an undertaking to repay such amounts if it is ultimately determined that the person is not entitled to be indemnified by us. Amending this provision will not reduce our indemnification obligations relating to actions taken before an amendment.

If Delaware law is amended to authorize corporate action further eliminating or limiting the personal liability of a director or officer, then the liability of our directors and officers will be eliminated or limited to the fullest extent permitted by Delaware law, as so amended. Our amended and restated certificate of incorporation does not eliminate a director’s or officer’s duty of care and, in appropriate circumstances, equitable remedies, such as injunctive or other forms of non-monetary relief, remain available under Delaware law. This provision also does not affect a director’s or officer’s responsibilities under any other laws, such as the federal securities laws or other state or federal laws. Our amended and restated bylaws will empower us to purchase insurance on behalf of any person whom we are required or permitted to indemnify.

Further, prior to the completion of this offering, we expect to enter into indemnification agreements with each member of our board of directors and our officers. These agreements will provide for the indemnification of our directors and officers for certain expenses and liabilities incurred in connection with any action, suit, proceeding, or alternative dispute resolution mechanism or hearing, inquiry, or investigation that may lead to the foregoing, to which they are a party, or are threatened to be made a party, by reason of the fact that they are or were a director, officer, employee, agent or fiduciary of us, or any of our subsidiaries, by reason of any action or inaction by them while serving as an officer, director, agent or fiduciary, or by reason of the fact that they were serving at our request as a director, officer, employee, agent, or fiduciary of another entity. In the case of an action or proceeding by or in the right of us or any of our subsidiaries, no indemnification will be provided for any claim where a court determines that the indemnified party is prohibited from receiving indemnification. We believe that these charter and bylaw provisions and indemnification agreements are necessary to attract and retain qualified persons as directors and officers.

The limitation of liability and indemnification provisions in our amended and restated certificate of incorporation and amended and restated bylaws may discourage stockholders from bringing a lawsuit against directors for breach of their fiduciary duties. They may also reduce the likelihood of derivative litigation against directors and officers, even though an action, if successful, might benefit us and our stockholders. Moreover, a stockholder’s investment may be harmed to the extent we pay the costs of settlement and damage awards against directors and officers pursuant to these indemnification provisions. Insofar as indemnification for liabilities arising under the Securities Act of 1933, as amended, or the Securities Act, may be permitted to our directors, officers, and controlling persons pursuant to the foregoing provisions, or otherwise, we have been advised that, in the opinion of the SEC, such indemnification is against public policy as expressed in the Securities Act, and is,

 

265


Table of Contents

therefore, unenforceable. There is no pending litigation or proceeding naming any of our directors or officers as to which indemnification is being sought, nor are we aware of any pending or threatened litigation that may result in claims for indemnification by any director or officer.

Forum Selection

The Court of Chancery of the State of Delaware will be the sole and exclusive forum for (i) any derivative action or proceeding brought on our behalf, (ii) any action asserting a claim of breach of fiduciary duty owed by any of our directors, officers or other employees to us or our stockholders, (iii) any action asserting a claim arising pursuant to any provision of the DGCL, or (iv) any action asserting a claim governed by the internal affairs doctrine.

These provisions will not apply to suits brought to enforce a duty or liability created by the Securities Exchange Act of 1934, as amended, or the Exchange Act. Our amended and restated certificate of incorporation will further provide that the federal district courts of the United States of America will be the exclusive forum for resolving any complaint asserting a cause or causes of action arising under the Securities Act, including all causes of action asserted against any defendant to such complaint although there is uncertainty as to whether a court would enforce this provision. The exclusive forum provisions may limit a stockholder’s ability to bring a claim in a judicial forum that it finds favorable for disputes with us or any of our directors, officers or stockholders, which may discourage lawsuits with respect to such claims. In addition, while the Delaware courts have determined that such choice of forum provisions are facially valid, a stockholder may nevertheless seek to bring a claim in a venue other than those designated in the exclusive forum provisions and there can be no assurance that these provisions will be enforced by a court in those other jurisdictions. In this regard, stockholders may not be deemed to have waived our compliance with the federal securities laws and the rules and regulations thereunder, including Section 22 of the Securities Act. Any person or entity purchasing or otherwise acquiring any interest in our shares of capital stock shall be deemed to have notice of and consented to the foregoing forum selection provisions. See “Risk Factors—Risks Relating to this Offering and Ownership of Our Class A Common Stock—Our amended and restated certificate of incorporation will designate the Court of Chancery of the State of Delaware or the federal district courts of the United States of America, as applicable, as the sole and exclusive forum for certain types of actions and proceedings that may be initiated by our stockholders, which could limit our stockholders’ ability to obtain a favorable judicial forum for disputes with the Company or the Company’s directors, officers or other employees.”

Listing

We have applied to list our Class A common stock on the NYSE under the symbol “VG.”

Transfer Agent and Registrar

The transfer agent and registrar for the Class A common stock is Equiniti Trust Company, LLC.

 

266


Table of Contents

DESCRIPTION OF MATERIAL FINANCING

The following information is a summary of the material terms of agreements representing certain indebtedness of our subsidiaries. Reference is made to the more detailed provisions of, and the descriptions are qualified in their entirety by reference to, these documents, copies of which are filed with the SEC as exhibits to the registration statement of which this prospectus forms a part.

Project Debt Financing

Calcasieu Project

Calcasieu Pass Credit Facilities

On August 19, 2019, VGCP, as borrower and TCP, as obligor, entered into a senior secured first lien construction facility equal to $5,477 million, or the Construction/Term Facility, and a senior secured working capital facility equal to $300 million, which was subsequently upsized to $555 million, or, as upsized, the Working Capital Facility, and, together with the Construction/Term Facility, the Calcasieu Pass Credit Facilities, with Natixis, New York Branch, as credit facility agent, Mizuho Bank (USA), as collateral agent, and the lenders party thereto to fund the costs of developing, constructing and commissioning the Calcasieu Project. The Calcasieu Pass Credit Facilities have a final maturity date of August 19, 2026.

On August 5, 2021, VGCP prepaid approximately $2.1 billion of indebtedness outstanding under the Construction/Term Facility by using the proceeds from the offering of the VGCP 2029 Notes and the VGCP 2031 Notes described below and, on November 22, 2021, VGCP prepaid approximately $1.0 billion of indebtedness outstanding under the Construction/Term Facility by using the proceeds from the offering of the VGCP 2033 Notes described below, and on January 13, 2023, VGCP prepaid approximately $1.0 billion of indebtedness outstanding under the Construction/Term Facility by using the proceeds from the offering of the VGCP 2030 Notes, also described below.

During the years ended December 31, 2022 and 2021, VGCP drew $0.6 billion and $2.3 billion, respectively, under the Calcasieu Pass Credit Facilities. As of September 30, 2024, December 31, 2023 and December 31, 2022, VGCP had $1.0 billion, $1.2 billion and $2.3 billion, respectively, outstanding under the Construction/Term Facility. The Construction/Term Facility was fully drawn as of December 31, 2022. In addition, VGCP had $254 million, $339 million and $553 million of outstanding letters of credit under the Working Capital Facility as of September 30, 2024 December 31, 2023 and December 31, 2022, respectively, which reduced the available borrowing capacity under the Working Capital Facility by an equivalent amount.

In June 2023, we modified the Calcasieu Pass Credit Facilities to transition its variable rate interest from LIBOR to SOFR. Borrowings under the Calcasieu Pass Credit Facilities bear interest at a set margin rate over the debt term, plus, at VGCP’s election, either a SOFR, plus a term SOFR adjustment, or base rate. The set margin rate for SOFR-based loans ranges from 2.38% to 2.88%. The set margin rate for base rate loans ranges from 1.38% to 1.88%. The term SOFR adjustment is either (i) 0.10% for a one-month term; (ii) 0.15% for a three-month term or (iii) 0.25% for a six-month term. VGCP can select a SOFR rate for a specific term of one month, three months, or six months in length, or a base rate that is the greatest of (i) the federal funds effective rate plus 0.50%, (ii) the bank prime rate, or (iii) one-month SOFR plus 1.10%. Interest on SOFR-based loans is due and payable at the end of each interest period (but at least every three months) and interest on base rate loans is due and payable at the end of each calendar quarter. VGCP also incurs quarterly commitment fees based on the undrawn commitment of the Calcasieu Pass Credit Facilities and certain letter of credit fees.

The principal of the loans made under the Construction/Term Facility must be repaid in quarterly installments. VGCP made the first of such amortization payments on March 31, 2023 and has continued to make quarterly payments as required under the Construction/Term Facility.

 

267


Table of Contents

The Calcasieu Pass Credit Facilities also contain mandatory prepayment provisions that require prepayment upon certain asset dispositions, recovery events, issuances of debt and impairments of certain SPAs. VGCP may voluntarily prepay the Calcasieu Pass Credit Facilities on three business days’ notice without premium or penalty.

The Calcasieu Pass Credit Facilities contain customary affirmative and negative covenants, that, among other things, limit VGCP’s ability to incur additional indebtedness, undertake fundamental changes, create liens, make investments, dispose of assets, pay distributions or other restricted payments, or enter into new material project documents, or undertake certain actions under such material project documents. Additionally, VGCP must maintain a minimum historical debt service coverage ratio of 1.15:1 for the applicable period ending as of the end of any fiscal quarter, subject to limited exercises of equity cures.

The obligations of VGCP under the Construction/Term Facility are guaranteed by TCP and are secured by a first priority lien on substantially all of the assets of VGCP and TCP and by a pledge by Calcasieu Pass Pledgor, LLC, or CP Pledgor, of its limited liability company interests in VGCP and TCP, except that the real property rights held by TCP, including the rights of way related to the TransCameron Pipeline, are not encumbered by the security documents.

Calcasieu Common Terms Agreement

On August 19, 2019, VGCP and TCP entered into the Common Terms Agreement, or the Calcasieu Common Terms Agreement, with Natixis, New York Branch, as the facility agent for the lenders under the Calcasieu Pass Credit Facilities and Mizuho Bank, Ltd., as intercreditor agent, in order to set out certain provisions regarding, among other things: (a) common representations and warranties; (b) common covenants; and (c) common events of default under the documents including the agreement governing the Calcasieu Pass Credit Facilities. Future lenders under additional facility agreements may accede to the Calcasieu Common Terms Agreement.

Under the terms of the Calcasieu Common Terms Agreement, VGCP is required to hedge not less than 75%, but no more than 105%, of the variable interest rate exposure of its senior secured debt. VGCP is restricted from making distributions under agreements governing its indebtedness generally until, among other requirements, the completion of the construction of the Calcasieu Project, funding of a debt service reserve account equal to six months of debt service and achieving certain minimum historical and projected debt service coverage ratios of at least 1.25:1.00, provided that VGCP may make pre-completion distributions if it satisfies a number of conditions, including that the independent engineer has certified that it reasonably expects the Calcasieu Project completion date to be achieved by an agreed date certain (currently June 1, 2025) and that after giving effect to the distribution, VGCP and TCP will have sufficient funds to achieve the project completion date by such date certain.

Upon VGCP’s incurrence of any replacement debt, a portion of the Construction/Term Facility amounts outstanding and/or commitments in an amount equal to the amount of such replacement debt less certain provisions, costs, prepayment premiums, fees and expenses allowed pursuant to the Calcasieu Common Terms Agreement is required to be prepaid and/or cancelled, as the case may be.

The events of default set forth in the Calcasieu Common Terms Agreement constitute events of default under the Calcasieu Pass Credit Facilities. In the case of an uncured event of default (and after all applicable cure periods), the Calcasieu Pass Credit Facilities administrative agent may, or upon the direction of the required lenders under the Calcasieu Pass Credit Facilities must, accelerate all or any portion of the outstanding loans and other obligations due and payable under the Calcasieu Pass Credit Facilities or terminate all outstanding commitments thereunder. Such acceleration/termination is automatic following an event of default relating to bankruptcy/insolvency of VGCP, TCP, or CP Pledgor. Furthermore, if the Calcasieu Project does not commence commercial operation by the date certain noted above, an event of default under the Calcasieu Pass Credit Facilities will occur.

 

268


Table of Contents

Under the Calcasieu Common Terms Agreement, VGCP is required to comply with certain covenants in relation to its SPAs. Among other things, VGCP is required to maintain certain SPAs covering the Calcasieu Project, which provide for commitments to purchase a quantity of LNG that, in the aggregate, is at least equal to a base committed quantity of a certain mtpa for a period until the initial debt has been amortized and/or to replace such SPAs with SPAs with similar terms within 90 days of termination (subject to certain extension). VGCP must make a mandatory prepayment if (a) VGCP breaches the SPA maintenance covenant in the Calcasieu Common Terms Agreement or (b) with respect to any required SPA under the Calcasieu Common Terms Agreement, a required export authorization becomes impaired and VGCP does not provide a reasonable remediation plan within 30 days following such impairment, diligently pursue such remediation, and cause such remediation to be effective within 90 days following the occurrence of the impairment.

VGCP Senior Secured Notes

On August 5, 2021, VGCP issued $2.5 billion aggregate principal amount of senior secured notes, consisting of $1.25 billion of senior secured notes due 2029, or the VGCP 2029 Notes, and $1.25 billion of senior secured notes due 2031, or the VGCP 2031 Notes. The VGCP 2029 Notes bear interest at a rate of 3.875% per annum and the VGCP 2031 Notes bear interest at a rate of 4.125% per annum, with interest on each series of notes payable semi-annually in arrears on February 15 and August 15 of each year. The VGCP 2029 Notes will mature on August 15, 2029 and the VGCP 2031 Notes will mature on August 15, 2031.

On November 22, 2021, VGCP issued $1.25 billion aggregate principal amount of senior secured notes due 2033, or VGCP 2033 Notes. The VGCP 2033 Notes bear interest at a rate of 3.875% per annum, payable semi-annually in arrears on May 1 and November 1 of each year. The VGCP 2033 Notes will mature on November 1, 2033.

On January 13, 2023, VGCP issued $1.0 billion aggregate principal amount of senior secured notes due 2030, or the VGCP 2030 Notes, and together with the VGCP 2029 Notes, the VGCP 2031 Notes and the VGCP 2033 Notes, the VGCP Senior Secured Notes. The VGCP 2030 Notes bear interest at a rate of 6.250% per annum, payable semi-annually in arrears on January 15 and July 15 of each year, beginning July 15, 2023. The VGCP 2030 Notes will mature on January 15, 2030.

VGCP’s obligations under the VGCP Senior Secured Notes are guaranteed by TCP and may be guaranteed by certain of VGCP’s future domestic subsidiaries, if any. The VGCP Senior Secured Notes and the guarantees are secured by certain collateral, or the VGCP Collateral, and the VGCP Senior Secured Notes and the Calcasieu Pass Credit Facilities share equally in such VGCP Collateral. The VGCP Senior Secured Notes are governed by the base indenture dated August 5, 2021, or the Base Indenture, as supplemented with respect to each particular series of notes. The Base Indenture contains customary terms and events of default and certain covenants that, among other things, limit or restrict VGCP’s ability and the ability of TCP and certain of VGCP’s future subsidiaries, if any, to (i) make restricted payments, (ii) incur additional indebtedness or issue preferred stock, (iii) guarantee the obligations of others, (iv) assume, incur, permit or suffer to exist liens on VGCP’s or their respective assets, (v) create or permit to exist or become effective any consensual encumbrance on the ability of a restricted subsidiary to pay dividends, pay indebtedness owed to VGCP, TCP or any of VGCP’s other restricted subsidiaries, make loans or advances to VGCP, TCP or VGCP’s other restricted subsidiaries, or sell, lease or transfer any properties or assets to VGCP, TCP or any of VGCP’s other restricted subsidiaries, (vi) consolidate, merge or sell substantially all of VGCP’s or their respective assets or properties, (vii) make investments, loans or advances, (viii) enter into certain transactions or agreements with or for the benefit of VGCP’s or their respective affiliates, (ix) amend or modify certain material project agreements or certain qualifying SPAs, (x) enter into hedging agreements, (xi) maintain accounts and (xii) create subsidiaries.

At any time or from time to time, prior to February 15, 2029, VGCP may redeem the VGCP 2029 Notes, in whole or in part, at a redemption price equal to 100% of the aggregate principal amount of the VGCP 2029 Notes, plus the “make-whole” set forth in the Base Indenture, plus accrued and unpaid interest up to but excluding the redemption date. In addition, at any time or from time to time, on or after February 15, 2029,

 

269


Table of Contents

VGCP may redeem the VGCP 2029 Notes, in whole or in part, at a redemption price equal to 100% of the principal amount of the VGCP 2029 Notes to be redeemed, plus accrued and unpaid interest, if any, on the VGCP 2029 Notes redeemed up to but not including the redemption date.

At any time or from time to time, prior to February 15, 2031, VGCP may redeem the VGCP 2031 Notes, in whole or in part, at a redemption price equal to 100% of the aggregate principal amount of the VGCP 2031 Notes, plus the “make-whole” set forth in the Base Indenture, plus accrued and unpaid interest up to but excluding the redemption date. In addition, at any time or from time to time, on or after February 15, 2031, VGCP may redeem the VGCP 2031 Notes, in whole or in part, at a redemption price equal to 100% of the principal amount of the VGCP 2031 Notes to be redeemed, plus accrued and unpaid interest, if any, on the VGCP 2031 Notes redeemed up to but not including the redemption date.

At any time or from time to time, prior to May 1, 2033, VGCP may redeem the VGCP 2033 Notes, in whole or in part, at a redemption price equal to 100% of the aggregate principal amount of the VGCP 2033 Notes, plus the “make-whole” set forth in the first supplemental indenture to the Base Indenture, dated as of November 22, 2021, plus accrued and unpaid interest up to but excluding the redemption date. In addition, at any time or from time to time, on or after May 1, 2033, VGCP may redeem the VGCP 2033 Notes, in whole or in part, at a redemption price equal to 100% of the principal amount of the VGCP 2033 Notes to be redeemed, plus accrued and unpaid interest, if any, on the VGCP 2033 Notes redeemed up to but not including the redemption date.

At any time or from time to time, prior to October 15, 2029, VGCP may redeem the 2030 notes, in whole or in part, at a redemption price equal to 100% of the aggregate principal amount of the VGCP 2030 Notes, plus the “make-whole” set forth in the second supplemental indenture to the Base Indenture, dated as of January 13, 2023, plus accrued and unpaid interest up to but excluding the redemption date. In addition, at any time or from time to time, on or after October 15, 2029, VGCP may redeem the VGCP 2030 Notes, in whole or in part, at a redemption price equal to 100% of the principal amount of the VGCP 2030 Notes to be redeemed, plus accrued and unpaid interest, if any, on the VGCP 2030 Notes redeemed up to but not including the redemption date.

The VGCP Senior Secured Notes and the guarantees constitute VGCP’s and the guarantors’ direct and unconditional senior secured obligations and rank senior in right of payment to any of VGCP’s and the guarantors’ future indebtedness that is subordinated in right of payment to the VGCP Senior Secured Notes and the guarantees and are equal in right of payment with all of VGCP’s and the guarantors’ existing and future indebtedness that is not subordinated, including the Calcasieu Pass Credit Facilities. The VGCP Senior Secured Notes and the guarantees are effectively subordinated to all of VGCP’s and the guarantors’ indebtedness that is secured by assets, if any, other than the VGCP Collateral, to the extent of the value of such assets. The VGCP Senior Secured Notes and the guarantees are effectively senior to all of VGCP’s and the guarantors’ senior indebtedness that is unsecured to the extent of the value of the assets constituting the VGCP Collateral.

The VGCP Senior Secured Notes are not subject to the Calcasieu Common Terms Agreement.

As of September 30, 2024, December 31, 2023 and December 31, 2022, the aggregate principal amount of VGCP Senior Secured Notes outstanding was $4.8 billion, $4.8 billion and $3.8 billion, respectively.

Plaquemines Project

Plaquemines Credit Facilities

In May 2022, VGPL, as borrower, and Gator Express, as guarantor, obtained approximately $9.6 billion in project financing (consisting of an approximately $8.5 billion term loan facility, or the Plaquemines Construction Term Loan, and a $1.1 billion working capital revolving facility, or the Plaquemines Working Capital Facility) maturing on May 25, 2029, to fund the development and construction of Phase 1 of the Plaquemines Project. Proceeds from the Plaquemines Construction Term Loan are used to fund a portion of the costs of developing, constructing and commissioning the Plaquemines Project, and pay interest and associated debt transaction fees

 

270


Table of Contents

and expenses. The Plaquemines Working Capital Facility is used to secure letters of credit and provide working capital financing to VGPL. A portion of the proceeds from the project financing was used to prepay a bridge facility for the Plaquemines Project and pay fees and expenses incurred in connection with the project financing.

The project financing facilities were upsized in March 2023 to fund the development and construction of Phase 2 of the Plaquemines Project. The Plaquemines Credit Facilities are comprised of approximately $12.9 billion of the Plaquemines Construction Term Loan and $2.1 billion of the Plaquemines Working Capital Facility. The remaining proceeds from the upsized project financing will be used to fund the costs of financing, developing, constructing, and commissioning the Plaquemines Project.

As of September 30, 2024, December 31, 2023 and December 31, 2022, VGPL had $10.4 billion, $4.9 billion and $1.1 billion, respectively, outstanding, and $2.6 billion, $8.0 billion and $7.4 billion, respectively, available, under the Plaquemines Construction Term Loan. VGPL had $1.2 billion, $840 million and $253 million of outstanding letters of credit under the Plaquemines Working Capital facility as of September 30, 2024, December 31, 2023 and December 31, 2022, respectively, which reduced the available borrowing capacity under the Plaquemines Working Capital Facility by an equivalent amount.

Borrowings under the Plaquemines Credit Facilities bear interest at either the SOFR or base rate, plus an applicable margin. VGPL can select a SOFR for a specific term of one month up to six months in length or a base rate that is the greatest of (i) the federal funds effective rate plus 0.50%, (ii) the bank prime rate, or (iii) the one-month term SOFR reference rate plus 1.10%. The set margin rate for SOFR-based loans ranges from 1.975% to 2.625%. The set margin rate for base rate loans ranges from 0.875% to 1.375%. Interest on term SOFR loans is due and payable at the end of each interest period (but at least every three months) and interest on base rate loans is due and payable at the end of each calendar quarter.

The principal on the loans made under the Plaquemines Construction Term Loan must be repaid in quarterly installments, beginning upon the earlier of the first calendar quarter end date occurring three months following completion of Phase 1 of the Plaquemines Project or February 28, 2027. The outstanding principal of the Plaquemines Credit Facilities may be repaid, in whole or in part, at any time without premium or penalty (subject to breakage fees).

The obligations of VGPL under the Plaquemines Credit Facilities are guaranteed by Gator Express and secured by a first-priority lien on substantially all of the assets of VGPL and Gator Express and by a pledge by Plaquemines LNG Pledgor, LLC, or Plaquemines Pledgor, of its limited liability company interests in VGPL and Gator Express, except that the real property rights held by Gator Express, including the rights of way related to Gator Express Pipeline, are not encumbered by the security documents.

Plaquemines Common Terms Agreement

On March 13, 2023, in connection with the upsize of the Plaquemines Credit Facilities, VGPL and Gator Express entered into the Amended and Restated Common Terms Agreement with Natixis, New York Branch, as the credit facility agent for the lenders under the Plaquemines Credit Facilities and Royal Bank of Canada, as intercreditor agent, or the Plaquemines Common Terms Agreement, in order to set out certain provisions regarding, among other things: (a) common representations and warranties; (b) common covenants; and (c) common events of default under the agreement governing the Plaquemines Credit Facilities. Currently, only the Plaquemines Credit Facilities are subject to the Common Terms Agreement. Future lenders under additional facility agreements may accede to the Plaquemines Common Terms Agreement.

Under the terms of the Plaquemines Common Terms Agreement, VGPL is required to hedge not less than 75% but no more than 105% of the variable interest rate exposure of its senior secured debt. VGPL is restricted from making distributions under agreements governing its indebtedness generally until, among other requirements, the completion of the construction of both phases of the Plaquemines Project, funding of a debt

 

271


Table of Contents

service reserve account equal to six months of debt service and achieving certain minimum historical and projected debt service coverage ratios of at least 1.25:1.00, provided that VGPL may make pre-completion distributions if it satisfies a number of conditions, including that the independent engineer has certified that it reasonably expects the completion date of Phase 1 and Phase 2 of the Plaquemines Project to be achieved by certain agreed deadlines and that after giving effect to the distribution, VGPL and Gator Express will have sufficient funds to achieve the project completion date by such deadlines.

Upon VGPL’s incurrence of any replacement debt, a portion of the amounts outstanding and/or commitments in an amount equal to the amount of such replacement debt less certain provisions, costs, prepayment premiums, fees and expenses allowed pursuant to the Plaquemines Common Terms Agreement is required to be prepaid and/or cancelled, as the case may be.

The events of default set forth in the Plaquemines Common Terms Agreement constitute events of default under the Plaquemines Credit Facilities. In the case of an uncured event of default (and after all applicable cure periods), the Plaquemines Credit Facilities administrative agent may, or upon the direction of the required lenders under the Plaquemines Credit Facilities must, accelerate all or any portion of the outstanding loans and other obligations due and payable under the Plaquemines Credit Facilities or terminate all outstanding commitments thereunder. Such acceleration/termination is automatic following an event of default relating to bankruptcy/insolvency of VGPL, Gator Express, or Plaquemines Pledgor. Furthermore, if the Plaquemines Project does not commence commercial operation by a specified date certain (currently February 28, 2027 and December 31, 2027, with respect to Phase 1 and Phase 2 of the Plaquemines Project, respectively, and, in each case, subject to extension in certain cases), an event of default under the Plaquemines Credit Facilities will occur.

Under the Plaquemines Common Terms Agreement, VGPL is required to comply with certain covenants relating to its SPAs. Among other things, VGPL is required to maintain certain SPAs covering the Plaquemines Project that provide for commitments to purchase a quantity of LNG that, in the aggregate, is at least equal to a base committed quantity of a certain mtpa for a period of no shorter than the lesser of (i) 12 years and (ii) the period until the debt has been amortized and/or to replace them with qualifying SPAs, which must provide for commitments to purchase LNG in quantities at least equal to the base committed quantity under the SPA being replaced, within 90 days of termination of the foundation SPA (subject to certain extension). VGPL must make a mandatory prepayment if (a) VGPL breaches the SPA maintenance covenant in the Plaquemines Common Terms Agreement or (b) with respect to any required SPA under the Plaquemines Common Terms Agreement, a required export authorization becomes impaired and VGPL does not provide a reasonable remediation plan within 30 days following such impairment, diligently pursue such remediation, and cause such remediation to be effective within 90 days following the occurrence of the impairment.

Project Equity Financing

Calcasieu Pass Holdings, LLC Preferred Units

On May 25, 2019, Calcasieu Holdings and a fund associated with Stonepeak Infrastructure Partners, or Stonepeak Fund I, entered into a unit purchase agreement where Calcasieu Holdings agreed to issue and sell to Stonepeak Fund I, and Stonepeak Fund I agreed to purchase, from Calcasieu Holdings 4,000,000 preferred units of Calcasieu Holdings, or Holdings Preferred Units, for an aggregate purchase price of $400 million, or the Holdings Face Value. The transaction closed on August 19, 2019, or the Equity Financing Closing Date. The terms of the Holdings Preferred Units are set forth in the limited liability company agreement of Calcasieu Holdings, dated as of August 19, 2019. Calcasieu Holdings applied the proceeds from the sale of the Holdings Preferred Units to fund the equity portion of the costs of developing, constructing and commissioning the Calcasieu Project and for other related business purposes of Calcasieu Holdings and its subsidiaries.

As of September 30, 2024, we owned 100% of the outstanding Class A common units of Calcasieu Holdings, or Class A Common Units, Stonepeak Fund I owned 100% of the outstanding Holdings Preferred Units and there were no outstanding Class B common units of Calcasieu Holdings, or Class B Common Units.

 

272


Table of Contents

Ranking

The Holdings Preferred Units rank senior to all Class A Common Units and Class B Common Units of Calcasieu Holdings, or Holdings Common Units, and to each other class of units of Calcasieu Holdings established by the board of managers of Calcasieu Holdings, the terms of which do not expressly provide that it ranks senior to or pari passu with the Holdings Preferred Units.

Distributions on Holdings Preferred Units

Until the eighth anniversary of the Equity Financing Closing Date, each outstanding Holdings Preferred Unit will receive distributions in-kind in the form of additional Holdings Preferred Units, or Holdings PIK Units, at 10.0% per annum. From and after such eighth anniversary, the Holdings PIK Units will accrue at 10.0% per annum, plus an additional 0.50% for every six month period, but will not exceed 15.0% per annum. The Holdings PIK Units will be cumulative. Calcasieu Holdings has an option to pay any portion of such distributions in cash.

Distributions on Holdings Common Units

For each full month prior to the Holdings Conversion (as defined below), distributions on the Holdings Common Units must be paid from the net proceeds from the sale of commissioning cargos from the Calcasieu Project, on the monthly distribution date following such declaration by the board to the members holding Holdings Common Units. Following the Holdings Conversion, distributions on the Holdings Common Units must be paid from available cash at Calcasieu Holdings, net of certain payments on indebtedness and reserves, on a quarterly basis.

Conversion into Class B Common Units and Mandatory Redemption

Upon the earlier of (a) commencement of commercial operation of the Calcasieu Project or (b) both (i) the occurrence of a Liquidation Event (as defined below) (or certain merger, amalgamation or consolidation involving VGLNG, Calcasieu Holdings or Calcasieu Funding, or an initial public offering of Calcasieu Holdings or any of its subsidiaries that holders of Holdings Preferred Units elect to treat as a Liquidation Event, or an Elected Liquidation Event) and (ii) the election by Stonepeak Fund I to convert, all Holdings Preferred Units, including any Holdings PIK Units outstanding, will automatically be converted to Class B Common Units of Calcasieu Holdings, or the Holdings Conversion. If Stonepeak Fund I does not elect to convert the Holdings Preferred Units to Class B Common Units in connection with an Elected Liquidation Event, Calcasieu Holdings is required to redeem the Holdings Preferred Units at an agreed liquidation price. As of September 30, 2024, the outstanding amount of the Holdings Preferred Units was approximately $586 million. Assuming that we service all future distributions on the Holdings Preferred Units until the commencement of COD in cash, the Holdings Preferred Units are expected to automatically convert into a number of Class B Common Units of Calcasieu Holdings equal to approximately 23% of the outstanding Holdings Common Units. As a result, after the conversion, we are expected to own 100% of the outstanding Class A Common Units, equal to approximately 77% of the outstanding Holdings Common Units, while Stonepeak Fund I is expected to own 100% of the outstanding Class B Common Units, equal to approximately 23% of the outstanding Holdings Common Units, and there will be no outstanding Holdings Preferred Units.

Approvals Required

Prior to the Holdings Conversion, holders of Holdings Preferred Units have the right to select and appoint one manager to the board of managers of Calcasieu Holdings (or when the Step-In Rights (as defined below) are exercised, two managers), and after the Holdings Conversion, holders of Class B Common Units shall have the same right. Such manager’s consent is required prior to Calcasieu Holdings or its subsidiaries taking the following actions, among others:

 

   

amending key project contracts, including the Calcasieu EPC Contract, the engineering, procurement and construction agreement for the construction of the TransCameron Pipeline, and any of the

 

273


Table of Contents
 

Calcasieu Foundation SPAs, or, collectively, the Key Project Contracts, if such amendment could reasonably be expected to have an adverse effect in any material respect on Calcasieu Holdings and its subsidiaries, taken as a whole;

 

   

incurring any additional indebtedness in excess of $75.0 million, except for refinancing of the debt financing described in “—Project Debt Financing—Calcasieu Project—Calcasieu Pass Credit Facilities”, debt incurred prior to commercial operation of the Calcasieu Project solely to fund construction and operation costs of the Calcasieu Project, a working capital facility or in connection with any additional or expansion LNG project, in each case as specified under the limited liability company agreement of Calcasieu Holdings; and

 

   

entering into any transaction with Calcasieu Funding (defined below), Stonepeak Fund I or any of their respective affiliates or any new contract or agreement with Venture Global LNG, Inc., Calcasieu Funding or any of their affiliates or amending any such existing contract, if the terms and conditions thereof are not commercially reasonable (from the perspective of Calcasieu Holdings and its subsidiaries) and are more favorable to Calcasieu Funding, Stonepeak Fund I or any of their respective affiliates than could be obtained on an arm’s length basis.

Step-In Right

If any of the following events occurs (subject to certain cure rights), then holders of Holdings Preferred Units (or holders of Class B Common Units after Holdings Conversion) will have the right to appoint two out of three managers to the board of managers of Calcasieu Holdings, or the Step-In Right, and members holding Class A Common Units will have the right to appoint one manager until and for so long as the circumstances that triggered such Step-In Right are continuing:

 

   

an event of default under the Calcasieu Pass Credit Facilities or inability of VGCP to draw loans under the Calcasieu Pass Credit Facilities for a period of at least 60 consecutive days as a result of the failure to satisfy the conditions precedent therein;

 

   

a material breach by Calcasieu Holdings or any of its subsidiaries under any of the Key Project Contracts that could, if uncured, result in termination of such Key Project Contract or the termination of any Key Project Contract;

 

   

a material breach under the Funding LLC Agreement (defined below) that is adverse to the holders of Funding Preferred Units in a material respect;

 

   

a significant casualty or condemnation event or loss of the DOE export license related to the Calcasieu Project or any other material permit, license, approval or authorization issued or granted by any governmental authority that results in the cessation of commercial operations of the Calcasieu Project in the ordinary course of business for at least 30 days;

 

   

a delay in commencement of the commercial operations of the Calcasieu Project beyond 45 days prior to the date certain under the Calcasieu Common Terms Agreement;

 

   

Accrued Distributions (as defined below) at Calcasieu Funding occurring for six consecutive calendar quarters commencing with the first full quarter following commencement of commercial operations at the Calcasieu Project;

 

   

the aggregate amount of Accrued Distributions outstanding on the Funding Preferred Units following commencement of commercial operations at the Calcasieu Project exceeds 25.0% of the aggregate principal amount (including then outstanding Accrued Distributions) of the outstanding Funding Preferred Units as of the date on which the Calcasieu Project commences commercial operations; and

 

   

Calcasieu Holdings not meeting the reasonable standard and expectation in operating the Calcasieu Project and as a result the annual aggregate liquefaction capacity of the Calcasieu Project being less than 75% of annual 10.0 mtpa aggregate nameplate capacity of the Calcasieu Project for three consecutive years following commencement of commercial operations of the Calcasieu Project, except to the extent caused by force majeure.

 

274


Table of Contents

In the event that the circumstances that triggered the Step-In Rights are no longer continuing, then members holding Class A Common Units will have the right to appoint two managers and members holding Holdings Preferred Units (or holders of Class B Common Units after Holdings Conversion) will have the right to appoint one manager of the board of managers of Calcasieu Holdings.

Liquidation Preference

In the event of any liquidation, dissolution or winding up of or bankruptcy, insolvency or other similar event in respect of Calcasieu Holdings, whether voluntary or involuntary, or Liquidation Event, a holder of Holdings Preferred Units will be entitled to be paid in cash, before any amount is paid or distributed to any holders of Holdings Common Units, an amount per Holdings Preferred Unit equal to the Holdings Face Value, as increased by the Holdings PIK Units and any accrued but unpaid distributions thereon.

Calcasieu Pass Funding, LLC Preferred Units

On May 25, 2019, Calcasieu Funding and a fund associated with Stonepeak Infrastructure Partners, or Stonepeak Fund II, entered into a unit purchase agreement where Calcasieu Funding agreed to issue and sell to Stonepeak Fund II and Stonepeak Fund II agreed to purchase from Calcasieu Funding 9,000,000 perpetual preferred units of Calcasieu Funding, or Funding Preferred Units for an aggregate purchase price of $900 million. The transaction closed on the Equity Financing Closing Date. The terms of the Funding Preferred Units are set forth in the limited liability company agreement of Calcasieu Funding, dated as of August 19, 2019, or the Funding LLC Agreement. Calcasieu Funding applied a portion of the proceeds from the sale of the Funding Preferred Units as a contribution to Calcasieu Holdings to be used by Calcasieu Holdings to fund the equity portion of the costs of developing, constructing and commissioning the Calcasieu Project.

As of September 30, 2024, we owned 100% of the outstanding Common Units of Calcasieu Funding, or Funding Common Units, while Stonepeak Fund II owned 100% of the outstanding Funding Preferred Units.

Ranking

The Funding Preferred Units rank senior to all Funding Common Units and to each other class of units of Calcasieu Funding established by Calcasieu Holdings, as the managing member of Calcasieu Funding, or the Managing Member.

Distributions on Funding Preferred Units

Until the eighth anniversary of the Equity Financing Closing Date, each outstanding Funding Preferred Unit will receive distributions at 10.0% per annum either (i) from certain available cash at Calcasieu Funding, net of reserves and cash required for certain permitted tax distributions, or the Calcasieu Funding Available Amount, if so declared by the Managing Member or (ii) in the form of an increase in the Funding Face Value, or an Accrued Distribution, where the “Funding Face Value” is an initial value of $100 for each Funding Preferred Unit, as may be increased by Accrued Distributions as of the last day of each applicable quarter. From and after such eighth anniversary, the Funding Preferred Units will receive distributions, either in cash or in the form of Accrued Distribution, at 10.0% per annum, plus an additional 0.50% for every six month period, but will not exceed 15.0% per annum. After COD of the Calcasieu Project, the Accrued Distribution will be at a rate per annum equal to 1.0% per annum above the applicable distribution rate. The distributions are cumulative and the Accrued Distributions will increase the Funding Face Value of each Funding Preferred Unit. As of September 30, 2024, the outstanding amount of the Funding Preferred Units was approximately $1.5 billion.

Distributions on Funding Common Units

For each full month prior to COD of the Calcasieu Project, distributions on the Funding Common Units must be paid from the net proceeds from the sale of commissioning cargos from the Calcasieu Project, on the monthly distribution date determined by the Managing Member.

 

275


Table of Contents

Following COD of the Calcasieu Project, but prior to the eighth anniversary of the Equity Financing Closing Date, distributions on Funding Common Units must be paid from the Calcasieu Funding Available Amount on a quarterly basis on each quarterly distribution date determined by the Managing Member, but only for so long as at the time of any such distribution (i) Calcasieu Funding has redeemed for cash any Accrued Distributions that have previously cumulated and accrued and (ii) the requisite amount of distribution in cash on the Funding Preferred Units is made on such quarterly distribution date such that no Accrued Distribution is made or outstanding on such quarterly distribution date.

Following the eighth anniversary of the Equity Financing Closing Date but prior to the date on which all of the outstanding Funding Preferred Units have been redeemed in full, or the Redeemed in Full Date, except for certain permitted tax distributions by Calcasieu Funding, (i) no distributions on Funding Common Units may be declared or paid and (ii) Calcasieu Funding shall use all Calcasieu Funding Available Amount to effect Redemptions (as defined and described below under “—Optional Redemption”) as soon as reasonably practicable and in any event on each quarterly distribution date.

Following the Redeemed in Full Date, distributions on Funding Common Units must be paid from the Calcasieu Funding Available Amount on a quarterly basis.

Optional Redemption

At any time on or after the third anniversary of the Equity Financing Closing Date, Calcasieu Funding has the right to cause (and, to the extent required as described in “—Distributions on Funding Common Units,” Calcasieu Funding shall cause) all or any portion of the outstanding Funding Preferred Units (including Accrued Distributions) to be redeemed (each such redemption, a Redemption) for cash at the agreed redemption price per Funding Preferred Unit set forth below (such amount, the Redemption Price):

 

   

if the date of Redemption is on or prior to the fourth anniversary of the Equity Financing Closing Date, an amount equal to the product of (a) 100% of the face value of such Funding Preferred Unit, as increased (without duplication, but including any accrual and any cumulation) by any Accrued Distributions, or the Base Return, multiplied by (b) 1.1;

 

   

if the date of Redemption is after the fourth anniversary of the Equity Financing Closing Date and on or prior to the fifth anniversary of the Equity Financing Closing Date, an amount equal to the product of the Base Return multiplied by 1.05;

 

   

if the date of Redemption is after the fifth anniversary of the Equity Financing Closing Date and on or prior to the sixth anniversary of the Equity Financing Closing Date, an amount equal to the product of the Base Return multiplied by 1.025; and

 

   

if the date of Redemption is after the sixth anniversary of the Equity Financing Closing Date, an amount equal to the Base Return.

Restrictions on Issuances of Additional Equity

Other than Calcasieu Holdings contributing capital in exchange for issuance of common units in Calcasieu Funding, Calcasieu Funding may not issue, offer or sell additional units without a majority approval of holders of outstanding Funding Preferred Units.

Liquidation Preference

In the event of any liquidation, dissolution or winding up of or bankruptcy, insolvency or other similar event in respect of Calcasieu Funding, whether voluntary or involuntary, a holder of Funding Preferred Units will be entitled to be paid in cash, before any amount is paid or distributed to any holders of Funding Common Units, an amount per Funding Preferred Unit equal to the Redemption Price.

 

276


Table of Contents

Other Financing

VGLNG Senior Secured Notes

On May 26, 2023, VGLNG issued $2.25 billion aggregate principal amount of VGLNG 2028 Notes and $2.25 billion aggregate principal amount of VGLNG 2031 Notes. The VGLNG 2028 Notes bear interest at a rate of 8.125% per annum and mature on June 1, 2028. The VGLNG 2031 Notes bear interest at a rate of 8.375% per annum and mature on June 1, 2031. The interest on each such series of notes is payable semi-annually in arrears on each June 1 and December 1. As of September 30, 2024, $2.25 billion aggregate principal amount of the VGLNG 2028 Notes remained outstanding and $2.25 billion aggregate principal amount of the VGLNG 2031 Notes was outstanding.

On October 24, 2023, VGLNG issued $2.50 billion aggregate principal amount of VGLNG 2029 Notes and $1.50 billion aggregate principal amount of VGLNG 2032 Notes. In addition, on November 8, 2023, VGLNG issued an additional $500 million aggregate principal amount of VGLNG 2029 Notes, and an additional $500 million aggregate principal amount of VGLNG 2032 Notes. The VGLNG 2029 Notes bear interest at a rate of 9.500% per annum and mature on February 1, 2029. The VGLNG 2032 Notes bear interest at 9.875% per annum and mature on February 1, 2032. The interest on each such series of notes is payable semi-annually in arrears on each February 1 and August 1, commencing on August 1, 2024. As of September 30, 2024, $3.0 billion aggregate principal amount of the VGLNG 2029 Notes remained outstanding and $2.0 billion aggregate principal amount of the VGLNG 2032 Notes was outstanding.

On July 24, 2024, VGLNG issued $1.50 billion aggregate principal amount of VGLNG 2030 Notes. The VGLNG 2030 Notes bear interest at a rate of 7.00% per annum and mature on January 15, 2030. The interest on such series of notes is payable semi-annually in arrears on each January 15 and July 15. As of September 30, 2024, $1.50 billion aggregate principal amount of the VGLNG 2030 Notes was outstanding.

The VGLNG 2028 Notes, the VGLNG 2029 Notes, the VGLNG 2030 Notes, the VGLNG 2031 Notes and the VGLNG 2032 Notes, or, collectively, the VGLNG Senior Secured Notes, were sold in a private offering that was exempt from the registration requirements of the Securities Act.

Guarantees and Security

The VGLNG Senior Secured Notes are senior secured obligations of VGLNG and, as of September 30, 2024, are not guaranteed by any other entities. In the future, certain of VGLNG’s subsidiaries that incur or guarantee certain amounts of indebtedness will also be required to guarantee the VGLNG Senior Secured Notes, except during any period, or the Suspension Period, when the VGLNG Senior Secured Notes are rated investment grade by any one of S&P, Moody’s or Fitch.

The VGLNG Senior Secured Notes and the related guarantees are secured by first-priority liens in, subject to permitted liens and certain other exceptions, substantially all of the existing and future assets of VGLNG and the future guarantors, if any, including the direct wholly-owned subsidiaries of VGLNG that directly or indirectly own the Calcasieu Project, the Plaquemines Project, the CP2 Project, the CP3 Project, the Delta Project or any related pipeline. The VGLNG Senior Secured Notes and the related guarantees of future guarantors, if any, will cease to be secured during any Suspension Period.

Optional Redemption

VGLNG may redeem some or all of (i) the VGLNG 2028 Notes at any time on or after June 1, 2025 and (ii) the VGLNG 2031 Notes at any time on or after June 1, 2026, in each case at the redemption prices set forth in the indenture governing such notes, plus accrued and unpaid interest, if any, to, but not including, the redemption

 

277


Table of Contents

date. Prior to June 1, 2025 and June 1, 2026, respectively, VGLNG may redeem some or all of such notes at 100% of the aggregate principal amount thereof redeemed plus a make-whole premium and accrued and unpaid interest, if any, to the redemption date. In addition, at any time prior to June 1, 2025 and June 1, 2026, respectively, VGLNG may redeem up to 40% of the then outstanding principal amount of such notes using the proceeds of certain equity offerings.

VGLNG may redeem some or all of (i) the VGLNG 2029 Notes at any time on or after November 1, 2028 and (ii) the VGLNG 2032 Notes at any time on or after February 1, 2027, in each case at the redemption prices set forth in the indenture governing such notes, plus accrued and unpaid interest, if any, to the redemption date. Prior to November 1, 2028 and February 1, 2027, respectively, VGLNG may redeem some or all of the notes at 100% of the aggregate principal amount thereof plus a make-whole premium and accrued and unpaid interest, if any, to the redemption date. In addition, with respect to the VGLNG 2032 Notes, at any time prior to February 1, 2027, VGLNG may redeem up to 40% of the then outstanding principal amount of the notes using the proceeds of certain equity offerings.

VGLNG may redeem some or all of the VGLNG 2030 Notes at any time on or after January 15, 2027 at the redemption prices set forth in the indenture governing such notes, plus accrued and unpaid interest, if any, to the redemption date. Prior to January 15, 2027, VGLNG may redeem some or all of the notes at 100% of the aggregate principal amount thereof plus a make-whole premium and accrued and unpaid interest, if any, to the redemption date. In addition, at any time prior to January 15, 2027, VGLNG may redeem up to 40% of the then outstanding principal amount of the notes using the proceeds of certain equity offerings.

Put Rights

Upon the occurrence of certain change of control triggering events with respect to the VGLNG Senior Secured Notes, VGLNG will be required to offer to repurchase the VGLNG Senior Secured Notes at a purchase price equal to 101% of the principal amount thereof plus accrued and unpaid interest, if any, to the purchase date.

Negative Covenants

Each indenture governing the VGLNG Senior Secured Notes contains covenants that limit the ability of VGLNG and its restricted subsidiaries to, among other things:

 

   

incur additional indebtedness, guarantee indebtedness or issue disqualified stock or, in the case of such subsidiaries, preferred stock;

 

   

pay dividends on, repurchase or make distributions in respect of their capital stock or make other restricted payments;

 

   

make certain investments or acquisitions;

 

   

sell, transfer or otherwise convey certain assets;

 

   

create liens;

 

   

enter into agreements restricting certain subsidiaries’ ability to pay dividends or make other intercompany transfers;

 

   

consolidate, merge, sell or otherwise dispose of all or substantially all of the assets of VGLNG and its restricted subsidiaries;

 

   

enter into certain transactions with affiliates; and

 

   

prepay certain kinds of indebtedness.

The covenants are subject to a number of exceptions and qualifications set forth in the indentures. In addition, certain of these covenants and the guarantee of each guarantor, if any, will be suspended during the Suspension Period.

 

278


Table of Contents

Events of Default

The indentures governing the VGLNG Senior Secured Notes also contain customary events of default, including (i) failure to pay principal or interest on the VGLNG Senior Secured Notes when due and payable; (ii) failure to comply with certain covenants or agreements in indenture if not cured or waived as provided in the indenture, as applicable and (iii) certain events of bankruptcy, insolvency, or reorganization. In the case of an event of default, the principal amount of the applicable VGLNG Senior Secured Notes plus accrued and unpaid interest would be accelerated.

If (1) a Change of Control (as defined in the indentures governing the VGLNG Senior Secured Notes) occurs and (2) the rating on the VGLNG Senior Secured Notes is lowered in respect of a Change of Control by two of S&P, Moody’s and Fitch, we must offer to repurchase the VGLNG Senior Secured Notes then outstanding at a price equal to 101% of the principal amount thereof plus any accrued and unpaid interest, if any, to, but not including, the repurchase date.

VGLNG Series A Preferred Shares

On September 30, 2024, VGLNG issued three million shares of 9.00% Series A Fixed-Rate Reset Cumulative Redeemable Perpetual Preferred Stock, with a $1,000 liquidation preference per share, or the VGLNG Series A Preferred Shares, for aggregate gross proceeds of $3.0 billion. The terms of the VGLNG Series A Preferred Shares are set forth in a certificate of designations, or the Certificate of Designations, filed with the Secretary of State of the State of Delaware.

The VGLNG Series A Preferred Shares have no stated maturity and are not subject to any mandatory redemption. The VGLNG Series A Preferred Shares will remain outstanding indefinitely unless VGLNG decides to redeem or otherwise repurchase them pursuant to the terms thereof. The VGLNG Series A Preferred Shares are not convertible into or exchangeable for any other securities or property and are not entitled to any preemptive or similar rights.

VGLNG used the proceeds from the offering of the VGLNG Series A Preferred Shares for general corporate purposes. The VGLNG Series A Preferred Shares were sold in a private offering that was exempt from the registration requirements of the Securities Act of 1933, as amended, or the Securities Act.

Ranking

The Series A Preferred Shares rank, with respect to semi-annual dividends and distributions upon the liquidation, winding-up and dissolution of VGLNG:

 

   

senior to any classes or series of common stock and to any other equity security issued by VGLNG other than an equity security referred to in the second or third bullet point below;

 

   

on a parity with any equity security issued by VGLNG with terms specifically providing that such equity security ranks on a parity with the VGLNG Series A Preferred Shares with respect to rights to the payment of dividends and/or distributions upon the liquidation, winding-up and dissolution of VGLNG’s affairs, as applicable;

 

   

junior to any equity security issued by VGLNG with terms specifically providing that such equity security ranks senior to the VGLNG Series A Preferred Shares with respect to rights to the payment of dividends and/or distributions upon the liquidation, winding-up and dissolution of VGLNG’s affairs, as applicable;

 

   

effectively junior to all existing and future indebtedness (including the VGLNG Senior Secured Notes and any indebtedness that may be convertible into VGLNG’s common stock or preferred stock) and other liabilities with respect to assets available to satisfy claims against VGLNG; and

 

279


Table of Contents
   

structurally subordinated to all existing and future indebtedness and other liabilities and preferred equity of VGLNG’s existing and future subsidiaries and existing and future capital stock of VGLNG’s existing and future subsidiaries held by third parties (including the Holdings Preferred Units, the Funding Preferred Units and the indebtedness outstanding under the Calcasieu Pass Credit Facilities, the Plaquemines Credit Facilities and the VGCP Senior Secured Notes).

Dividends

Cumulative cash dividends on the VGLNG Series A Preferred Shares are payable semi-annually, in arrears, on each March 30 and September 30, when, as and if declared by the board of directors of VGLNG. Dividends on the VGLNG Series A Preferred Shares accumulate whether or not (i) VGLNG has earnings, (ii) there are funds legally available for the payment of such dividends, (iii) payment of such dividends is then permitted under Delaware or other applicable law, (iv) such dividends are authorized or declared and (v) any agreements to which VGLNG is a party (including any agreements relating to its indebtedness) prohibit the payment of dividends.

The dividend rate for the VGLNG Series A Preferred Shares from and including September 30, 2024, to, but excluding, the First Reset Date, is 9.00% per annum of the $1,000 liquidation preference. On and after the First Reset Date, the dividend rate on the VGLNG Series A Preferred Shares for each subsequent five-year period will be a per annum rate of the $1,000 liquidation preference equal to the applicable five-year U.S. treasury rate, plus a spread of 5.44% per annum; provided that the five-year U.S. treasury rate for each such five-year period will not be lower than 1.00%.

Unless full cumulative dividends have been paid on all outstanding VGLNG Series A Preferred Shares through the most recent dividend payment date on which dividends were to be paid, subject to certain exceptions as set forth in the Certificate of Designations, VGLNG may not (i) declare, pay or set apart any dividend or distribution for payment on any junior securities (other than a dividend or distribution payable solely in junior securities and the liquidation, winding-up and dissolution of the affairs of VGLNG), including its common stock, and (ii) VGLNG may not redeem, purchase or otherwise acquire any parity security or junior security, including its common stock.

Voting rights

Holders of the VGLNG Series A Preferred Shares are entitled to limited voting rights, subject to certain exceptions, with respect to:

 

   

amendments to the certificate of incorporation of VGLNG that would materially adversely affect the powers, preferences, duties or special rights of the VGLNG Series A Preferred Shares;

 

   

the creation or issuance of any senior equity securities;

 

   

if any cumulative dividends on the VGLNG Series A Preferred Shares (or parity securities, if applicable) are in arrears, the creation or issuance of any parity securities; and

 

   

if any dividends on the VGLNG Series A Preferred Shares in respect of three consecutive semi-annual dividend periods are accumulated and unpaid, the election of two preferred stock directors to the VGLNG board of directors.

Optional redemption

At any time on or after the First Reset Date, VGLNG may, at its option, redeem, in whole or in part, on one or more occasions, the VGLNG Series A Preferred Shares at a redemption price payable in cash of $1,000 (100.00% of the liquidation preference) per VGLNG Series A Preferred Share, plus an amount equal to all accumulated and unpaid dividends thereon to, but excluding, the date of redemption, whether or not declared.

 

280


Table of Contents

At any time within 120 days after the conclusion of any review or appeal process instituted by VGLNG following the occurrence of certain rating events, VGLNG may, at its option, redeem the VGLNG Series A Preferred Shares in whole, but not in part, at a redemption price payable in cash equal to $1,020 (102.00% of the liquidation preference of $1,000) per VGLNG Series A Preferred Share, plus an amount equal to all accumulated and unpaid dividends thereon to, but excluding, the date fixed for redemption, whether or not declared.

At any time within 120 days after the occurrence of certain change of control trigger events with respect to the VGLNG Series A Preferred Shares, VGLNG may, at its option, redeem, in whole or in part, on one or more occasions, the VGLNG Series A Preferred Shares at a redemption price payable in cash of $1,030 (103.00% of the liquidation preference) per VGLNG Series A Preferred Share for a change of control trigger event that occurs before September 30, 2025, $1,020 (102.00% of the liquidation preference) per VGLNG Series A Preferred Share for a change of control trigger event that occurs on or after September 30, 2025 and before September 30, 2026 or $1,010 (101.00% of the liquidation preference) per VGLNG Series A Preferred Share for a change of control trigger event that occurs on or after September 30, 2026 and before September 30, 2029, plus an amount equal to all accumulated and unpaid dividends thereon to, but excluding, the date of redemption, whether or not declared. If VGLNG does not exercise its option to redeem all VGLNG Series A Preferred Shares within 120 days after the first date on which a change of control trigger event occurs, then the then-applicable dividend rate for the VGLNG Series A Preferred Shares will be increased by 5.00% with effect from, but excluding, such 120th day after the first day such change of control trigger event occurs.

Liquidation preference

In the event of VGLNG’s voluntary or involuntary liquidation, winding-up or dissolution, the holders of the VGLNG Series A Preferred Shares will be entitled to be paid out of the assets VGLNG has legally available for distribution to its shareholders, subject to the preferential rights of Senior Equity Securities with respect to such distribution, a liquidation preference of $1,000 per share, plus an amount equal to any accumulated and unpaid dividends thereon (whether or not earned or declared) to, but not including, the date of payment, before any distribution of assets upon such liquidation, winding-up or dissolution is made to holders of any junior securities with respect to such distribution.

In the event that, upon any such voluntary or involuntary liquidation, winding- up or dissolution, VGLNG’s available assets are insufficient to pay the amount of the liquidating distributions on all outstanding VGLNG Series A Preferred Shares and the corresponding amounts payable on all parity securities in the distribution of assets, then the holders of VGLNG Series A Preferred Shares and such other parity securities will share ratably in any such distribution of assets in proportion to the full liquidating distributions to which they would otherwise be respectively entitled.

 

281


Table of Contents

MATERIAL U.S. FEDERAL INCOME AND ESTATE TAX CONSEQUENCES

FOR NON-U.S. HOLDERS OF COMMON STOCK

The following are the material U.S. federal income and estate tax consequences of the ownership and disposition of our common stock acquired in this offering by a “Non-U.S. Holder” that does not own, and has not owned, actually or constructively, more than 5% of our common stock. You are a Non-U.S. Holder for U.S. federal income tax purposes if you are a beneficial owner of our common stock and are:

 

   

a nonresident alien individual;

 

   

a foreign corporation; or

 

   

a foreign estate or trust.

You are not a Non-U.S. Holder if you are a nonresident alien individual present in the United States for 183 days or more in the taxable year of disposition, or if you are a former citizen or former resident of the United States for U.S. federal income tax purposes. If you are such a person, you should consult your tax advisor regarding the U.S. federal income tax consequences of the ownership and disposition of our common stock.

If you are an entity or arrangement treated as a partnership for U.S. federal income tax purposes, the U.S. federal income tax treatment of a partner will generally depend on the status of the partner and your activities. Partners and beneficial owners in partnerships or other pass-through entities that own our common stock should consult their own tax advisors as to the particular U.S. federal income and estate tax consequences applicable to them.

This discussion is based on the Internal Revenue Code of 1986, as amended to the date hereof (the “Code”), administrative pronouncements, judicial decisions and final, temporary and proposed Treasury regulations, changes to any of which subsequent to the date of this prospectus may affect the tax consequences described herein, possibly with retroactive effect. This discussion does not describe all of the tax consequences that may be relevant to you in light of your particular circumstances, including alternative minimum tax and Medicare contribution tax consequences and does not address any aspect of state, local or non-U.S. taxation, or any taxes other than income and estate taxes. In addition, this summary does not describe the U.S. federal income tax consequences applicable to you if you are subject to special treatment under U.S. federal income tax laws, including if you are a U.S. expatriate, a financial institution, an insurance company, a tax-exempt organization, a trader, broker or dealer in securities or currencies, a “controlled foreign corporation,” a “passive foreign investment company,” a person who acquired shares of our common stock as compensation or otherwise in connection with the performance of services, or a person who has acquired shares of our common stock as part of a straddle, hedge, conversion transaction or other integrated investment. You should consult your tax advisor with regard to the application of the U.S. federal tax laws to your particular situation, as well as any tax consequences arising under the laws of any state, local or non-U.S. taxing jurisdiction.

We have not sought and do not expect to seek any rulings from the U.S. Internal Revenue Service (the “IRS”) regarding the matters discussed below. There can be no assurance that the IRS will not take positions concerning the tax consequences of the ownership or disposition of shares of our common stock that differ from those discussed below.

Dividends

In the event that we do make distributions of cash or other property, those distributions will constitute dividends for U.S. federal income tax purposes to the extent paid from our current or accumulated earnings and profits, as determined under U.S. federal income tax principles. To the extent those distributions exceed our current and accumulated earnings and profits, they will constitute a return of capital, which will first reduce your basis in our common stock, but not below zero, and then will be treated as gain from the sale of our common stock, as described below under “—Gain on Disposition of Our Common Stock.”

 

282


Table of Contents

Dividends paid to you generally will be subject to withholding tax at a 30% rate or a reduced rate specified by an applicable income tax treaty. In order to obtain a reduced rate of withholding, you will be required to provide a properly executed applicable IRS Form W-8 certifying your entitlement to benefits under a treaty. If you do not timely furnish the required documentation, but you qualify for a lower treaty rate, you may obtain a refund of any excess amounts withheld by timely filing an appropriate claim for refund with the IRS. You should consult your tax advisor regarding your entitlement to benefits under any applicable income tax treaty.

If dividends paid to you are effectively connected with your conduct of a trade or business in the United States (and, if required by an applicable income tax treaty, are attributable to a permanent establishment or fixed base maintained by you in the United States), you will generally be taxed on the dividends in the same manner as a U.S. person. In this case, you will be exempt from the withholding tax discussed in the preceding paragraph, although you will be required to provide a properly executed IRS Form W-8ECI in order to claim an exemption from withholding. You should consult your tax advisor with respect to other U.S. tax consequences of the ownership and disposition of our common stock, including the possible imposition of a branch profits tax at a rate of 30% (or a lower treaty rate) if you are a corporation.

Gain on Disposition of Our Common Stock

Subject to the discussion below under “—Information Reporting and Backup Withholding” you generally will not be subject to U.S. federal income or withholding tax on gain realized on a sale or other taxable disposition of our common stock unless:

 

   

the gain is effectively connected with your conduct of a trade or business in the United States (and, if required by an applicable income tax treaty, is attributable to a permanent establishment or fixed base maintained by you in the United States), or

 

   

we are or have been a “United States real property holding corporation” (a “USRPHC”) as described below, at any time within the five-year period preceding the disposition or your holding period, whichever period is shorter, and our common stock has ceased to be regularly traded on an established securities market prior to the beginning of the calendar year in which the sale or disposition occurs.

We will be a USRPHC at any time that the fair market value of our “United States real property interests,” as defined in the Code and applicable Treasury Regulations, equals or exceeds 50% of the aggregate fair market value of our worldwide real property interests and our other assets used or held for use in a trade or business. Based on the current composition of our assets, we believe that we are not currently a USRPHC. However, because (i) the determination of whether we are a USRPHC at any time depends on the fair market value of our U.S. real property relative to the fair market value of other business assets at such time, and (ii) we expect a significant portion of our assets to consist of United States real property interests once we begin construction of our projects, there can be no assurance that we will not become a USRPHC at any point in time in the future. If we are or were to become a USRPHC at any point during the five-year period preceding your sale or other disposition of our common stock (or during your holding period, if shorter) and our common stock is not regularly traded on an established securities market during the calendar year in which your sale or other disposition of our common stock occurs, you would be subject to tax on the net gain from the sale or other disposition of our common stock (including a distribution treated as a sale of our common stock, as discussed above) under the regular graduated U.S. federal income tax rates applicable to U.S. persons and you could be subject to withholding at a 15% rate on the amount realized on such sale or disposition. You should consult your tax advisor regarding the particular U.S. federal income tax consequences of owning and disposing of our common stock.

If you recognize gain on a sale or other disposition of our common stock that is effectively connected with your conduct of a trade or business in the United States (and if required by an applicable income tax treaty, is attributable to a permanent establishment or fixed base maintained by you in the United States), you will generally be taxed on such gain in the same manner as a U.S. person. You should consult your tax advisor with

 

283


Table of Contents

respect to other U.S. tax consequences of the ownership and disposition of our common stock, including the possible imposition of a branch profits tax at a rate of 30% (or a lower treaty rate) if you are a corporation.

Information Reporting and Backup Withholding

Information returns are required to be filed with the IRS in connection with payments of distributions on our common stock, regardless of whether such distributions constitute dividends or whether any tax was actually withheld. Unless you comply with certification procedures to establish that you are not a U.S. person, information returns may also be filed with the IRS in connection with the proceeds from a sale or other disposition of our common stock. You may be subject to backup withholding on payments on our common stock or on the proceeds from a sale or other disposition of our common stock unless you comply with certification procedures to establish that you are not a U.S. person or otherwise establish an exemption. Your provision of a properly executed applicable IRS Form W-8 certifying your non-U.S. status will permit you to avoid backup withholding. Amounts withheld under the backup withholding rules are not additional taxes and may be refunded or credited against your U.S. federal income tax liability, provided the required information is timely furnished to the IRS.

FATCA

Provisions of the Code commonly referred to as “FATCA” require withholding of 30% on payments of dividends on our common stock to “foreign financial institutions” (which is broadly defined for this purpose and in general includes investment vehicles) and certain other non-U.S. entities unless various U.S. information reporting and due diligence requirements (generally relating to ownership by U.S. persons of interests in or accounts with those entities) have been satisfied, or an exemption applies. Under proposed regulations promulgated by the Treasury Department on December 13, 2018, which state that taxpayers may rely on the proposed regulation until final regulations are issued, this withholding tax will not apply to the gross proceeds from the sale or other disposition of our common stock. An intergovernmental agreement between the United States and an applicable foreign country may modify these requirements. If FATCA withholding is imposed, a beneficial owner that is not a foreign financial institution generally may obtain a refund of any amounts withheld by filing a U.S. federal income tax return (which may entail significant administrative burden). You should consult your tax advisor regarding the effects of FATCA on your investment in our common stock.

Federal Estate Tax

Individual Non-U.S. Holders and entities the property of which is potentially includible in such an individual’s gross estate for U.S. federal estate tax purposes (for example, a trust funded by such an individual and with respect to which the individual has retained certain interests or powers), should note that, absent an applicable treaty exemption, our common stock will be treated as U.S.-situs property subject to U.S. federal estate tax.

THE SUMMARY OF MATERIAL U.S. FEDERAL INCOME AND ESTATE TAX CONSIDERATIONS ABOVE IS INCLUDED FOR GENERAL INFORMATION PURPOSES ONLY. YOU ARE URGED TO CONSULT YOUR OWN TAX ADVISOR TO DETERMINE THE U.S. FEDERAL, STATE AND LOCAL AND NON-U.S. INCOME, ESTATE AND OTHER TAX CONSIDERATIONS OF OWNING AND DISPOSING OF OUR COMMON STOCK.

 

284


Table of Contents

SHARES ELIGIBLE FOR FUTURE SALE

Prior to this offering, there has been no market for our Class A common stock. Future sales of substantial amounts of our Class A common stock in the public market could adversely affect market prices prevailing from time to time. Furthermore, because only a limited number of shares will be available for sale shortly after this offering due to existing contractual and legal restrictions on resale as described below, there may be sales of substantial amounts of our Class A common stock in the public market after the restrictions lapse. This may adversely affect the prevailing market price and our ability to raise equity capital in the future.

Sales of Restricted Shares

Upon completion of this offering, a total of   shares of Class A common stock (assuming no exercise of the underwriters’ option to purchase additional shares) and   shares of Class B common stock will be outstanding. Of these shares, all of the Class A common stock sold in this offering by us, plus any shares sold by exercise of the underwriters’ option to purchase additional Class A common stock from us, will be freely tradable in the public market without restriction or further registration under the Securities Act, unless these shares are held by “affiliates,” as that term is defined in Rule 144 under the Securities Act. The remaining shares of Class A common stock and the shares of Class B common stock will be, and shares of Class A common stock subject to stock options will be on issuance, “restricted securities,” as that term is defined in Rule 144 under the Securities Act. These restricted securities are eligible for public sale only if they are registered under the Securities Act or if they qualify for an exemption from registration under Rule 144 or Rule 701 under the Securities Act, which are summarized below. Restricted securities may also be sold outside of the United States to non-U.S. persons in accordance with Rule 904 of Regulation S.

Subject to the lock-up arrangements described below and the provisions of Rule 144, Rule 701 or Regulation S under the Securities Act, as well as our insider trading policy, these restricted securities will be available for sale in the public market after the date of this prospectus as follows:

 

Number of Shares

  

Date

   On the date of this prospectus.
   After 180 days from the date of this prospectus (subject, in some cases, to volume limitations).

Rule 144

In general, a person who has beneficially owned restricted shares of our common stock for at least six months would be entitled to sell such securities, provided that (i) such person is not deemed to have been one of our affiliates at the time of, or at any time during the 90 days preceding, a sale and (ii) we are subject to the Exchange Act periodic reporting requirements for at least 90 days before the sale. Persons who have beneficially owned restricted shares of our common stock for at least six months but who are our affiliates at the time of, or any time during the 90 days preceding, a sale, would be subject to additional restrictions, by which such person would be entitled to sell within any three month period only a number of securities that does not exceed the greater of either of the following:

 

   

1% of the number of shares of our Class A common stock then outstanding, which will equal approximately    shares immediately after this offering, assuming no exercise of the underwriters’ option to purchase additional shares; or

 

   

the average weekly trading volume of our Class A common stock on the NYSE during the four calendar weeks preceding the filing of a notice on Form 144 with respect to the sale;

provided, in each case, that we are subject to the Exchange Act periodic reporting requirements for at least 90 days before the sale. Such sales both by affiliates and by non-affiliates must also comply with the manner of sale, current public information and notice provisions of Rule 144 to the extent applicable.

 

285


Table of Contents

Rule 701

In general, under Rule 701, any of our employees, directors, officers, consultants or advisors who purchases shares from us in connection with a compensatory stock or option plan or other written agreement before the effective date of this offering is entitled to resell such shares 90 days after the effective date of this offering in reliance on Rule 144, without having to comply with the holding period requirements or other restrictions contained in Rule 701.

The SEC has indicated that Rule 701 will apply to typical stock options granted by an issuer before it becomes subject to the reporting requirements of the Exchange Act, along with the shares acquired upon exercise of such options, including exercises after the date of this prospectus. Securities issued in reliance on Rule 701 are restricted securities and, subject to the contractual restrictions described above, beginning 90 days after the date of this prospectus, may be sold by persons other than “affiliates,” as defined in Rule 144, subject only to the manner of sale provisions of Rule 144 and by “affiliates” under Rule 144 without compliance with its one-year minimum holding period requirement.

Registration Rights

Following completion of this offering, holders of   shares of Class A common stock and   shares of Class B common stock will be entitled to various rights with respect to the registration of these shares under the Securities Act. Registration of these shares under the Securities Act would result in these shares becoming freely tradable without restriction under the Securities Act immediately upon the effectiveness of the registration, except for shares purchased by affiliates. See “Certain Relationships and Related Party Transactions—Amended and Restated Shareholders’ Agreement”

Stock Options

Upon completion of this offering, we expect that options to purchase a total of   shares of Class A common stock will be outstanding, including options to purchase a total of     shares of Class A common stock pursuant to the IPO Grants. Of such shares,    shares subject to options are subject to lock-up arrangements and/or certain market stand-off provisions pursuant to the 2023 Plan. See “Underwriting.” An additional   shares of Class A common stock are expected to be available for future grants under our equity incentive plans.

Upon completion of this offering, we intend to file one or more registration statements on Form S-8 under the Securities Act covering all shares of Class A common stock subject to outstanding options or issuable pursuant to our equity incentive plans. Subject to Rule 144 volume limitations applicable to affiliates, shares registered under any registration statements will be available for sale in the open market, beginning 90 days after the date of the prospectus, except to the extent that the shares are subject to vesting restrictions with us or the contractual restrictions described below.

Lock-up Arrangements

We have agreed, for a period of 180 days after the date of this prospectus and subject to certain exceptions, that we will not offer, pledge, sell, contract to sell, grant any option or contract to purchase, purchase any option or contract to sell, grant any option, right or warrant to purchase, lend, or otherwise transfer or dispose of, directly or indirectly, or submit to, or file with, the SEC a registration statement under the Securities Act relating to, any shares of our Class A common stock or any securities convertible into or exercisable or exchangeable for our Class A common stock, or publicly disclose the intention to undertake any of the foregoing, or enter into any swap or other agreement that transfers, in whole or in part, any of the economic consequences of ownership of our Class A common stock or any such other securities, whether any such transaction described above is to be settled by delivery of our Class A common stock or such other securities, in cash or otherwise, without the prior written consent of the representatives of the underwriters for this offering, other than our Class A common stock to be sold hereunder.

 

286


Table of Contents

All of our directors, officers and our Pre-IPO Stockholders are subject to lock-up restrictions pursuant to which, subject to certain exceptions, they may not offer, pledge, sell, contract to sell, sell any option or contract to purchase, purchase any option or contract to sell, grant any option, right or warrant to purchase, lend, or otherwise transfer or dispose of, directly or indirectly, any shares of our Class A common stock or any securities convertible into or exercisable or exchangeable for our Class A common stock, enter into any hedging, swap or other agreement or transaction that transfers, in whole or in part, any of the economic consequences of ownership of such securities, whether any of these transactions are to be settled by delivery of our Class A common stock or other securities, in cash or otherwise, make any demand for or exercise any right with respect to the registration of any such securities or publicly disclosing the intention of doing any of the foregoing, in each case, without the prior written consent of the representatives of the underwriters for this offering, for a period of 180 days after the date of this prospectus.

In addition, holders of options to purchase Class A common stock outstanding immediately prior to closing of this offering (other than the IPO Grants) are subject to certain market stand-off provisions pursuant to the 2023 Plan for 180 days from the date of this prospectus, except with prior written consent of us or the underwriters.

For more information, see “Underwriting.”

 

287


Table of Contents

UNDERWRITING

We and the underwriters named below have entered into an underwriting agreement with respect to the shares of our Class A common stock being offered in this offering. Subject to certain conditions, each underwriter has severally agreed to purchase the number of shares of our Class A common stock indicated in the following table. Goldman Sachs & Co. LLC, J.P. Morgan Securities LLC and BofA Securities, Inc. are the representatives of the underwriters.

 

Underwriters

   Number of
Shares
 

Goldman Sachs & Co. LLC

          

J.P. Morgan Securities LLC

  

BofA Securities, Inc.

  

ING Financial Markets LLC

  

RBC Capital Markets, LLC

  

Scotia Capital (USA) Inc.

  

Mizuho Securities USA LLC

  

Santander US Capital Markets LLC

  

SMBC Nikko Securities America, Inc.

  

MUFG Securities Americas Inc.

  

BBVA Securities Inc.

  

Loop Capital Markets LLC

  

Natixis Securities Americas LLC

  

Deutsche Bank Securities Inc.

  
  

 

 

 

Total

  
  

 

 

 

The underwriters are committed to take and pay for all of the shares of our Class A common stock being offered in this offering, if any are taken, other than the shares of our Class A common stock covered by the option described below unless and until this option is exercised.

The underwriters have an option to buy up to an additional   shares of our Class A common stock from us to cover sales by the underwriters of a greater number of shares of our Class A common stock than the total number set forth in the table above. They may exercise that option for 30 days after the date of this prospectus. If any shares of our Class A common stock are purchased pursuant to this option, the underwriters will severally purchase shares of our Class A common stock in approximately the same proportion as set forth in the table above.

The following table shows the per share and total underwriting discounts and commissions to be paid to the underwriters by us. Such amounts are shown assuming both no exercise and full exercise of the underwriters’ option to purchase additional shares of our Class A common stock from us.

 

     No-Exercise      Full-Exercise  

Per Share

   $        $    

Total

   $        $    

Shares of our Class A common stock sold by the underwriters to the public will initially be offered at the initial public offering price set forth on the cover of this prospectus. Any shares of our Class A common stock sold by the underwriters to securities dealers may be sold at a discount of up to $    per share from the initial public offering price. After the initial offering of the shares of our Class A common stock, the representatives may change the offering price and the other selling terms. The offering of the shares of our Class A common stock by the underwriters is subject to receipt and acceptance and subject to the underwriters’ right to reject any order in whole or in part.

 

288


Table of Contents

We have agreed that we will not (i) offer, pledge, sell, contract to sell, sell any option or contract to purchase, purchase any option or contract to sell, grant any option, right or warrant to purchase, lend or otherwise transfer or dispose of, directly or indirectly, or submit to, or file with, the SEC a registration statement under the Securities Act relating to, any shares of our Class A common stock or securities convertible into or exercisable or exchangeable for any shares of our Class A common stock, or publicly disclose the intention to undertake any of the foregoing, or (ii) enter into any swap or other agreement that transfers, in whole or in part, any of the economic consequences of ownership of any shares of Class A common stock or any such other securities (whether any such transaction described in clause (i) or (ii) above is to be settled by delivery of shares of Class A common stock or such other securities, in cash or otherwise), without the prior written consent of the representatives of the underwriters for a period of 180 days after the date of this prospectus (such period, the “restricted period”), other than the shares of our Class A common stock to be sold in this offering.

The restrictions described above do not apply to certain transactions, subject to certain exceptions, including (i) Class A common stock to be sold in this offering, (ii) the conversion of certain shares of Class A common stock into Class B common stock as described in this prospectus, (iii) the establishment or amendment of a trading plan on behalf of one of our stockholders, officers or directors pursuant to Rule 10b5-1 under the Exchange Act, or a 10b5-1 Plan, (iv) the offer or issuance or agreement by us to issue Class A common stock or securities convertible into, exercisable for or which are otherwise exchangeable for or represent the right to receive Class A common stock in connection with an acquisition, merger, joint venture, strategic alliance, commercial or other collaborative relationship or the acquisition or license by us or any of our subsidiaries of the securities, business, property or other assets of another person or entity or pursuant to any employee benefit plan as assumed by us in connection with any such acquisition or transaction, provided that the aggregate number of shares of Class A common stock, securities convertible into, exercisable for or which are otherwise exchangeable for or represent the right to receive Class A common stock that we may sell or issue or agree to sell or issue pursuant to this clause (iv) shall not exceed 10.0% of the total number of shares of our Class A common stock outstanding immediately following the issuance of Class A common stock in this offering and also that the recipients thereof sign a lock-up agreement substantially in the same form, (v) conversions of Class B common stock into Class A common stock pursuant to the terms of our certificate of incorporation, (vi) the issuance of shares of Class A common stock or securities convertible into or exercisable for shares of Class A common stock pursuant to the conversion or exchange of convertible or exchangeable securities or the exercise of warrants or options or similar awards (including net exercise) or the settlement of RSUs or other equity-based awards (including net settlement) as described in this prospectus, (vii) grants of stock options, stock awards, restricted stock, RSUs, or other equity or equity-based awards and the issuance of shares of Class A common stock or securities convertible into or exercisable or exchangeable for shares of Class A common stock (whether upon the exercise of stock options or otherwise) to our employees, officers, directors, advisors, consultants or prospective employees or officers, pursuant to the terms of an equity compensation plan described in this prospectus or (viii) the filing of any registration statement on Form S-8 relating to securities granted or to be granted pursuant to any equity compensation plan described in this prospectus.

Our directors, executive officers and substantially all of our Pre-IPO Stockholders have entered into lock-up agreements with the underwriters prior to the commencement of this offering, and the remaining Pre-IPO Stockholders are subject to substantially similar lock-up arrangements in the Amended and Restated Shareholders’ Agreement (all of the persons subject to lock-up restrictions described herein, the “lock-up parties”), pursuant to which each lock-up party, with limited exceptions, for the restricted period), may not (and may not cause any of their direct or indirect affiliates to), without the prior written consent of the representatives of the underwriters for this offering, (i) offer, pledge, sell, contract to sell, sell any option or contract to purchase, purchase any option or contract to sell, grant any option, right or warrant to purchase, lend or otherwise transfer or dispose of, directly or indirectly, any shares of our Class A common stock or any securities convertible into or exercisable or exchangeable for our Class A common stock (including, without limitation, Class A common stock or such other securities which may be deemed to be beneficially owned by such lock-up parties in accordance with the rules and regulations of the SEC and securities which may be issued upon exercise of a stock option or warrant (collectively with Class A common stock, the “lock-up securities”)), (ii) enter into any

 

289


Table of Contents

hedging, swap or other agreement or transaction that transfers, in whole or in part, any of the economic consequences of ownership of the lock-up securities, whether any such transaction described in clause (i) or (ii) above is to be settled by delivery of lock-up securities, in cash or otherwise, (iii) make any demand for, or exercise any right with respect to, the registration of any lock-up securities, provided that, to the extent any holder (as defined below) has demand and/or piggyback registration rights to require registration, the foregoing shall not prohibit such holder from notifying the Company privately that it will be exercising such demand and/or piggyback registration rights following the expiration of the restricted period and undertaking any non-public preparations related thereto, provided further that (A) no transfers of the lock-up securities registered pursuant to the exercise of any such right shall be made, and no registration statement shall be publicly filed under the Securities Act with respect to any of the lock-up securities during the restricted period and (B) for the avoidance of doubt, no press release shall be issued in connection with the registration by us of any such securities (including in connection with the confidential submission of any registration statement with the SEC) during the restricted period, or (iv) publicly disclose the intention to do any of the foregoing. Such persons or entities have further acknowledged that these undertakings preclude them from engaging in any hedging or other transactions or arrangements (including, without limitation, any short sale or the purchase or sale of, or entry into, any put or call option, or combination thereof, forward, swap or any other derivative transaction or instrument, however described or defined) designed or intended, or which could reasonably be expected to lead to or result in, a sale or disposition or transfer (by any person or entity, whether or not a signatory to such agreement) of any economic consequences of ownership, in whole or in part, directly or indirectly, of any lock-up securities, whether any such transaction or arrangement (or instrument provided for thereunder) would be settled by delivery of lock-up securities, in cash or otherwise.

The restrictions described in the immediately preceding paragraph and contained in such lock-up arrangements do not apply, subject in certain cases to various conditions, to certain transactions, including (i) transfers, distributions or dispositions of lock-up securities: (A) as a bona fide gift or gifts, or for bona fide estate planning purposes; (B) by will, other testamentary document or intestacy; (C) to any trust for the direct or indirect benefit of the lock-up party or its immediate family, or if the lock-up party is a trust, to a trustor or beneficiary of the trust or to the estate of a beneficiary of such trust; (D) to a corporation, partnership, limited liability company or other entity of which the lock-up party and/or its immediate family members are the legal and beneficial owner of all of the outstanding equity securities or similar interests; (E) to a nominee or custodian of a person or entity to whom a transfer, distribution or disposition would be permissible under clauses (A) through (D); (F) if the lock-up securities are held by a corporation, partnership, limited liability company, trust or other business entity, or the holders, (x) to another corporation, partnership, limited liability company, trust or other business entity that is an affiliate of the holder, or to any investment fund or other entity controlling, controlled by, managing or managed by or under common control with the holder or its affiliates (including, for the avoidance of doubt, where the holder’s lock-up securities are held by a partnership, to its general partner or a successor partnership or fund, or any other funds managed by such partnership) or (y) as part of a distribution to members, partners, shareholders or other equityholders of the holder; (G) by operation of law, such as pursuant to a qualified domestic order, divorce settlement, divorce decree, separation agreement or other court order; (H) to us from a current or former employee upon death, disability or termination of employment of such employee; (I) as part of a sale or transfer of lock-up securities acquired in this offering or in open market transactions after the completion of this offering; (J) as part of a sale of the lock-up party’s lock-up securities acquired in open market transactions after the closing date of this offering; (K) to us in connection with the vesting, settlement or exercise of restricted stock units, options, warrants or other equity or equity based awards or rights with respect to or to purchase shares of our Class A common stock, or equity based grants, including for the payment of exercise price and tax, remittance and other obligations due as a result of the vesting, settlement, or exercise of such equity based grants (in each case, whether by way of “net” or “cashless” exercise, “net settlement” or otherwise); or (L) pursuant to a bona fide third-party tender offer, merger, consolidation or other similar transaction approved by our board of directors and made to all stockholders involving a change in control, provided that if such transaction is not completed, all such lock-up securities shall remain subject to the restrictions in the immediately preceding paragraph; (ii) exercise of outstanding options, settle restricted stock units or other equity awards or exercise warrants pursuant to plans described in in this prospectus, provided that any lock-up securities received

 

290


Table of Contents

upon such exercise, vesting or settlement would be subject to restrictions similar to those in the immediately preceding paragraph; (iii) the conversion of outstanding preferred stock, warrants to acquire preferred stock or convertible securities into shares of lock-up securities or warrants to acquire lock-up securities; provided that any such shares of Class A common stock or warrants received upon such conversion would be subject to restrictions similar to those in the immediately preceding paragraph; (iv) the establishment by lock-up parties of trading plans under Rule 10b5-1, or the 10b5-1 Plan, under the Exchange Act, provided that such plan does not provide for the transfer of lock-up securities during the restricted period, and provided further that no filing by any person under the Exchange Act or other public announcement shall be voluntarily made and that any public announcement or filing under the Exchange Act is required to be made by any person in connection with the establishment of such 10b5-1 plan during the restricted period shall include a statement that the lock-up party is not permitted to transfer, sell or otherwise dispose of securities under such 10b5-1 plan during the restricted period in contravention with the immediately preceding paragraph; and (v) the conversion, reclassification or exchange of shares of our Class A common stock into shares of our Class B common stock as described in this prospectus, or the conversion, reclassification or exchange of shares of our Class B common stock into shares of our Class A common stock pursuant to the terms of our Class B common stock, provided that any lock-up securities received upon such conversion, reclassification or exchange would be subject to restrictions similar to those in the immediately preceding paragraph.

In addition, holders of options to purchase Class A common stock outstanding immediately prior to closing of this offering (other than the IPO Grants) are subject to certain market stand-off provisions pursuant to the 2023 Plan for 180 days from the date of this prospectus, except with prior written consent of us or the underwriters.

The representatives of the underwriters for this offering, in their sole discretion, may release the securities subject to any of the lock-up arrangements described above, in whole or in part at any time.

We have applied to list our Class A common stock on the NYSE under the symbol “VG.”

In connection with this offering, the underwriters may purchase and sell shares of our Class A common stock in the open market. These transactions may include short sales, stabilizing transactions, and purchases to cover positions created by short sales. Short sales involve the sale by the underwriters of a greater number of shares than they are required to purchase in this offering, and a short position represents the amount of such sales that have not been covered by subsequent purchases. A “covered short position” is a short position that is not greater than the amount of additional shares for which the underwriters’ option described above may be exercised. The underwriters may cover any covered short position by either exercising their option to purchase additional shares or purchasing shares in the open market. In determining the source of shares to cover the covered short position, the underwriters will consider, among other things, the price of shares available for purchase in the open market as compared to the price at which they may purchase additional shares pursuant to the option described above. “Naked” short sales are any short sales that create a short position greater than the amount of additional shares for which the option described above may be exercised. The underwriters must cover any such naked short position by purchasing shares in the open market. A naked short position is more likely to be created if the underwriters are concerned that there may be downward pressure on the price of the common stock in the open market after pricing that could adversely affect investors who purchase in the offering. Stabilizing transactions consist of various bids for or purchases of common stock made by the underwriters in the open market prior to the completion of the offering.

The underwriters may also impose a penalty bid. This occurs when a particular underwriter repays to the underwriters a portion of the underwriting discount received by it because the representatives have repurchased shares sold by or for the account of such underwriter in stabilizing or short covering transactions.

Purchases to cover a short position and stabilizing transactions, as well as other purchases by the underwriters for their own accounts, may have the effect of preventing or retarding a decline in the market price of our Class A common stock, and together with the imposition of the penalty bid, may stabilize, maintain, or otherwise affect the market price of our Class A common stock. As a result, the price of our Class A common

 

291


Table of Contents

stock may be higher than the price that otherwise might exist in the open market. The underwriters are not required to engage in these activities and may end any of these activities at any time. These transactions may be effected on the NYSE, in the over-the-counter market, or otherwise.

We estimate that the total expenses of this offering, excluding underwriting discounts and commissions, will be approximately $    . We have agreed to reimburse the underwriters for certain of their expenses relating to the clearance of this offering with the Financial Industry Regulatory Authority in an amount up to $    .

We have agreed to indemnify the several underwriters against certain liabilities, including liabilities under the Securities Act of 1933, as amended, and to contribute to payments that the underwriters may be required to make for these liabilities.

Pricing of the Offering

Prior to this offering, there has been no public market for our Class A common stock. The initial public offering price was determined by negotiations between us and the representatives of the underwriters. In determining the initial public offering price, we and the representatives of the underwriters expect to consider a number of factors including: the information set forth in this prospectus and otherwise available to the representatives; our prospects and the history and prospects for the industry in which we compete; an assessment of our management; our current earnings and prospects for future earnings; the general condition of the securities markets at the time of this offering; the recent market prices of, and demand for, publicly traded common stock of comparable high growth industrial and technology companies; and other factors deemed relevant by the underwriters and us.

Relationships with the Underwriters and Their Affiliates

The underwriters and their respective affiliates are full service financial institutions engaged in various activities, which may include lending, sales and trading, commercial and investment banking, advisory, investment management, investment research, principal investment, hedging, market making, brokerage, and other financial and non-financial activities and services. Certain of the underwriters and their respective affiliates have provided, and may in the future provide, a variety of these services to us and to persons and entities with relationships with us, for which they received or will receive customary fees and expenses.

In the ordinary course of their various business activities, the underwriters and their respective affiliates, officers, directors, and employees may purchase, sell, or hold a broad array of investments and actively trade securities, derivatives, loans, commodities, currencies, credit default swaps, and other financial instruments for their own account and for the accounts of their customers, and such investment and trading activities may involve or relate to our assets, securities, and/or instruments (directly, as collateral securing other obligations, or otherwise) and/or persons and entities with relationships with us. The underwriters and their respective affiliates may also communicate independent investment recommendations, market color or trading ideas, and/or publish or express independent research views in respect of such assets, securities, or instruments and may at any time hold, or recommend to clients that they should acquire, long and/or short positions in such assets, securities, and instruments.

Selling Restrictions

Notice to Prospective Investors in the European Economic Area

In relation to each European Economic Area Member State, or each a Relevant Member State, no shares of our Class A common stock have been offered or will be offered pursuant to this offering to the public in that Relevant Member State prior to the publication of a prospectus in relation to the shares of our Class A common stock which has been approved by the competent authority in that Relevant Member State or, where appropriate, approved in another Relevant Member State and notified to the competent authority in that Relevant Member State, all in accordance with the Prospectus Regulation, except that the shares of our Class A common stock may be offered to the public in that Relevant Member State at any time:

 

   

to any legal entity which is a qualified investor as defined under Article 2 of the Prospectus Regulation;

 

292


Table of Contents
   

to fewer than 150 natural or legal persons (other than qualified investors as defined under Article 2 of the Prospectus Regulation) subject to obtaining the prior consent of the joint book-running managers for any such offer; or

 

   

in any other circumstances falling within Article 1(4) of the Prospectus Regulation;

provided that no such offer of the shares of our Class A common stock shall require us or any underwriter to publish a prospectus pursuant to Article 3 of the Prospectus Regulation or supplement a prospectus pursuant to Article 23 of the Prospectus Regulation.

For the purposes of this provision, the expression an “offer to the public” in relation to the shares of our Class A common stock in any Relevant Member State means the communication in any form and by any means of sufficient information on the terms of the offer and any shares of our Class A common stock to be offered so as to enable an investor to decide to purchase any shares of our Class A common stock, and the expression “Prospectus Regulation” means Regulation (EU) 2017/1129.

Each person in a Relevant Member State who receives any communication in respect of, or who acquires any shares of our Class A common stock in, this offering will be deemed to have represented, warranted, and agreed to and with each of the underwriters and their affiliates and us that:

 

   

it is a qualified investor within the meaning of the Prospectus Regulation; and

 

   

in the case of any shares of our Class A common stock acquired by it as a financial intermediary, as that term is used in Article 5 of the Prospectus Regulation, (i) the shares of our Class A common stock acquired by it in this offering have not been acquired on a non-discretionary basis on behalf of, nor have they been acquired with a view to their offer or resale to, persons in any Relevant Member State other than qualified investors, as that term is defined in the Prospectus Regulation, or have been acquired in other circumstances falling within the points (a) to (d) of Article 1(4) of the Prospectus Regulation and the prior consent of the joint book-running managers has been given to the offer or resale; or (ii) where the shares of our Class A common stock have been acquired by it on behalf of persons in any Relevant Member State other than qualified investors, the offer of those shares of our Class A common stock to it is not treated under the Prospectus Regulation as having been made to such persons.

We, the underwriters and their affiliates, and others will rely upon the truth and accuracy of the foregoing representation, acknowledgement, and agreement. Notwithstanding the above, a person who is not a qualified investor and who has notified the joint book-running managers of such fact in writing may, with the prior consent of the joint book-running managers, be permitted to acquire shares of our Class A common stock in this offering.

This European Economic Area selling restriction is in addition to any other selling restrictions set out below.

Notice to Prospective Investors in the United Kingdom

In relation to the United Kingdom, no shares of our Class A common stock have been offered or will be offered pursuant to this offering to the public in the United Kingdom prior to the publication of a prospectus in relation to the shares of our Class A common stock which has been approved by the Financial Conduct Authority in accordance with the transition provisions in Regulation 74 of the Prospectus (Amendment etc.) (EU Exit) Regulations 2019, except that it may make an offer to the public in the United Kingdom of any shares of our Class A common stock at any time under the following exemptions under the UK Prospectus Regulation:

 

   

to any legal entity which is a qualified investor as defined under Article 2 of the UK Prospectus Regulation;

 

   

to fewer than 150 natural or legal persons (other than qualified investors as defined under the UK Prospectus Regulation), subject to obtaining the prior consent of the representatives for any such offer; or

 

293


Table of Contents
   

in any other circumstances falling within section 86 of the Financial Services and Markets Act 2000, as amended, or the FSMA;

provided that no such offer of the shares of our Class A common stock shall require the issuer or any underwriter to publish a prospectus pursuant to section 85 of the FSMA or supplement a prospectus pursuant to Article 23 of the UK Prospectus Regulation.

In the United Kingdom, this offering is only addressed to, and is directed only at, “qualified investors” within the meaning of Article 2(e) of the UK Prospectus Regulation, who are also (i) persons having professional experience in matters relating to investments who fall within the definition of “investment professionals” in Article 19(5) of the Financial Services and Markets Act 2000 (Financial Promotion) Order 2005, as amended, or the Order; (ii) high net worth entities or other persons falling within Article 49(2)(a) to (d) of the Order; or (iii) persons to whom it may otherwise lawfully be communicated, or all such persons being referred to as relevant persons. This document must not be acted on or relied on by persons who are not relevant persons. Any investment or investment activity to which this document relates is available only to relevant persons and will be engaged in only with relevant persons.

For the purposes of this provision, the expression an “offer to the public” in relation to the shares of our Class A common stock in the United Kingdom means the communication in any form and by any means of sufficient information on the terms of the offering and any shares of our Class A common stock to be offered so as to enable an investor to decide to purchase or subscribe for any shares of our Class A common stock, and the expression “UK Prospectus Regulation” means the Regulation (EU) 2017/1129 as it forms part of domestic law by virtue of the European Union (Withdrawal) Act 2018.

Each person in the UK who acquires any shares of our Class A common stock in the offer or to whom any offer is made will be deemed to have represented, acknowledged, and agreed to and with us, the underwriters, and their affiliates that it meets the criteria outlined in this section.

Notice to Prospective Investors in Canada

The shares of our Class A common stock may be sold in Canada only to purchasers purchasing, or deemed to be purchasing, as principal that are accredited investors, as defined in National Instrument 45-106 Prospectus Exemptions or subsection 73.3(1) of the Securities Act (Ontario), and are permitted clients, as defined in National Instrument 31-103 Registration Requirements, Exemptions, and Ongoing Registrant Obligations. Any resale of the shares of our Class A common stock must be made in accordance with an exemption from, or in a transaction not subject to, the prospectus requirements of applicable securities laws.

Securities legislation in certain provinces or territories of Canada may provide a purchaser with remedies for rescission or damages if this prospectus (including any amendment thereto) contains a misrepresentation, provided that the remedies for rescission or damages are exercised by the purchaser within the time limit prescribed by the securities legislation of the purchaser’s province or territory. The purchaser should refer to any applicable provisions of the securities legislation of the purchaser’s province or territory of these rights or consult with a legal advisor.

Pursuant to section 3A.3 of National Instrument 33-105 Underwriting Conflicts (NI 33-105), the underwriters are not required to comply with the disclosure requirements of NI 33-105 regarding underwriter conflicts of interest in connection with this offering.

Notice to Prospective Investors in Hong Kong

The shares of our Class A common stock may not be offered or sold in Hong Kong by means of any document other than (i) in circumstances which do not constitute an offer to the public within the meaning of the

 

294


Table of Contents

Companies (Winding Up and Miscellaneous Provisions) Ordinance (Cap. 32 of the Laws of Hong Kong), or the Companies (Winding Up and Miscellaneous Provisions) Ordinance, or which do not constitute an invitation to the public within the meaning of the Securities and Futures Ordinance (Cap. 571 of the Laws of Hong Kong), or the Securities and Futures Ordinance, or (ii) to “professional investors” as defined in the Securities and Futures Ordinance and any rules made thereunder, or (iii) in other circumstances which do not result in the document being a “prospectus” as defined in the Companies (Winding Up and Miscellaneous Provisions) Ordinance, and no advertisement, invitation or document relating to the shares of our Class A common stock may be issued or may be in the possession of any person for the purpose of issue (in each case whether in Hong Kong or elsewhere), which is directed at, or the contents of which are likely to be accessed or read by, the public in Hong Kong (except if permitted to do so under the securities laws of Hong Kong) other than with respect to shares which are or are intended to be disposed of only to persons outside Hong Kong or only to “professional investors” in Hong Kong as defined in the Securities and Futures Ordinance and any rules made thereunder.

Notice to Prospective Investors in Singapore

This prospectus has not been registered as a prospectus with the Monetary Authority of Singapore. Accordingly, this prospectus and any other document or material in connection with the offer or sale, or invitation for subscription or purchase, of the shares of our Class A common stock may not be circulated or distributed, nor may the shares of our Class A common stock be offered or sold, or be made the subject of an invitation for subscription or purchase, whether directly or indirectly, to persons in Singapore other than (i) to an institutional investor (as defined under Section 4A of the Securities and Futures Act, Chapter 289 of Singapore, or the SFA) under Section 274 of the SFA, (ii) to a relevant person (as defined in Section 275(2) of the SFA) pursuant to Section 275(1) of the SFA, or any person pursuant to Section 275(1A) of the SFA, and in accordance with the conditions specified in Section 275 of the SFA or (iii) otherwise pursuant to, and in accordance with the conditions of, any other applicable provision of the SFA, in each case subject to conditions set forth in the SFA.

Where the shares of our Class A common stock are subscribed or purchased under Section 275 of the SFA by a relevant person which is a corporation (which is not an accredited investor (as defined in Section 4A of the SFA)) the sole business of which is to hold investments and the entire share capital of which is owned by one or more individuals, each of whom is an accredited investor, the securities (as defined in Section 239(1) of the SFA) of that corporation shall not be transferable for six months after that corporation has acquired the shares under Section 275 of the SFA except: (1) to an institutional investor under Section 274 of the SFA or to a relevant person (as defined in Section 275(2) of the SFA), (2) where such transfer arises from an offer in that corporation’s securities pursuant to Section 275(1A) of the SFA, (3) where no consideration is or will be given for the transfer, (4) where the transfer is by operation of law, (5) as specified in Section 276(7) of the SFA, or (6) as specified in Regulation 32 of the Securities and Futures (Offers of Investments) (Shares and Debentures) Regulations 2005 of Singapore, or Regulation 32.

Where the shares of our Class A common stock are subscribed or purchased under Section 275 of the SFA by a relevant person which is a trust (where the trustee is not an accredited investor (as defined in Section 4A of the SFA)) whose sole purpose is to hold investments and each beneficiary of the trust is an accredited investor, the beneficiaries’ rights and interest (howsoever described) in that trust shall not be transferable for six months after that trust has acquired the shares of our Class A common stock under Section 275 of the SFA except: (1) to an institutional investor under Section 274 of the SFA or to a relevant person (as defined in Section 275(2) of the SFA), (2) where such transfer arises from an offer that is made on terms that such rights or interest are acquired at a consideration of not less than S$200,000 (or its equivalent in a foreign currency) for each transaction (whether such amount is to be paid for in cash or by exchange of securities or other assets), (3) where no consideration is or will be given for the transfer, (4) where the transfer is by operation of law, (5) as specified in Section 276(7) of the SFA, or (6) as specified in Regulation 32.

Singapore SFA Product Classification — In connection with Section 309B of the SFA and the Securities and Futures (Capital Markets Products) Regulations 2018, or the CMP Regulations 2018, we have determined,

 

295


Table of Contents

and hereby notify all relevant persons (as defined in the CMP Regulations 2018), that the shares of our Class A common stock are “prescribed capital markets products” (as defined in the CMP Regulations 2018) and Excluded Investment Products (as defined in MAS Notice SFA 04-N12: Notice on the Sale of Investment Products and MAS Notice FAA-N16: Notice on Recommendations on Investment Products).

Notice to Prospective Investors in Japan

The shares of our Class A common stock have not been and will not be registered under the Financial Instruments and Exchange Act of Japan (Act No. 25 of 1948, as amended), or the FIEA. The shares of our Class A common stock may not be offered or sold, directly or indirectly, in Japan or to or for the benefit of any resident of Japan (including any person resident in Japan or any corporation or other entity organized under the laws of Japan) or to others for reoffering or resale, directly or indirectly, in Japan or to or for the benefit of any resident of Japan, except pursuant to an exemption from the registration requirements of the FIEA and otherwise in compliance with any relevant laws and regulations of Japan.

Notice to Prospective Investors in Switzerland

The shares of our Class A common stock may not be publicly offered in Switzerland and will not be listed on the SIX Swiss Exchange, or SIX, or on any other stock exchange or regulated trading facility in Switzerland. This document does not constitute a prospectus within the meaning of, and has been prepared without regard to the disclosure standards for issuance prospectuses under art. 652a or art. 1156 of the Swiss Code of Obligations or the disclosure standards for listing prospectuses under art. 27 ff. of the SIX Listing Rules or the listing rules of any other stock exchange or regulated trading facility in Switzerland. Neither this document nor any other offering or marketing material relating to the shares or this offering may be publicly distributed or otherwise made publicly available in Switzerland.

Neither this document nor any other offering or marketing material relating to this offering, us or the shares of our Class A common stock have been or will be filed with or approved by any Swiss regulatory authority. In particular, this document will not be filed with, and the offer of shares of our Class A common stock will not be supervised by, the Swiss Financial Market Supervisory Authority, and the offer of shares of our Class A common stock has not been and will not be authorized under the Swiss Federal Act on Collective Investment Schemes, or CISA. The investor protection afforded to acquirers of interests in collective investment schemes under the CISA does not extend to acquirers of shares of our Class A common stock.

Notice to Prospective Investors in Australia

No placement document, prospectus, product disclosure statement, or other disclosure document has been lodged with the Australian Securities and Investments Commission in relation to this offering. This prospectus does not constitute a prospectus, product disclosure statement, or other disclosure document under the Corporations Act 2001, or the Corporations Act, and does not purport to include the information required for a prospectus, product disclosure statement, or other disclosure document under the Corporations Act.

Any offer in Australia of the shares of our Class A common stock may only be made to persons, or the Exempt Investors, who are “sophisticated investors” (within the meaning of section 708(8) of the Corporations Act), “professional investors” (within the meaning of section 708(11) of the Corporations Act), or otherwise pursuant to one or more exemptions contained in section 708 of the Corporations Act so that it is lawful to offer the shares of our Class A common stock without disclosure to investors under Chapter 6D of the Corporations Act.

The shares of our Class A common stock applied for by Exempt Investors in Australia must not be offered for sale in Australia in the period of 12 months after the date of allotment under this offering, except in circumstances where disclosure to investors under Chapter 6D of the Corporations Act would not be required pursuant to an exemption under section 708 of the Corporations Act or otherwise or where the offer is pursuant to a disclosure document which complies with Chapter 6D of the Corporations Act. Any person acquiring shares of our Class A common stock must observe such Australian on-sale restrictions.

 

296


Table of Contents

This prospectus contains general information only and does not take account of the investment objectives, financial situation, or particular needs of any particular person. It does not contain any securities recommendations or financial product advice. Before making an investment decision, investors need to consider whether the information in this prospectus is appropriate to their needs, objectives, and circumstances, and, if necessary, seek expert advice on those matters.

Notice to Prospective Investors in the Dubai International Financial Centre

This prospectus relates to an Exempt Offer in accordance with the Offered Securities Rules of the Dubai Financial Services Authority, or DFSA. This prospectus is intended for distribution only to persons of a type specified in the Offered Securities Rules of the DFSA. It must not be delivered to, or relied on by, any other person. The DFSA has no responsibility for reviewing or verifying any documents in connection with Exempt Offers. The DFSA has not approved this prospectus nor taken steps to verify the information set forth herein and has no responsibility for the prospectus. The shares of our Class A common stock to which this prospectus relates may be illiquid and/or subject to restrictions on their resale. Prospective purchasers of our Class A common stock should conduct their own due diligence on such shares. If you do not understand the contents of this prospectus, you should consult an authorized financial advisor.

Notice to Prospective Investors in the United Arab Emirates

The shares of our Class A common stock have not been, and are not being, publicly offered, sold, promoted or advertised in the United Arab Emirates (including the DIFC) other than in compliance with the laws of the United Arab Emirates (and the DIFC) governing the issue, offering and sale of securities. Further, this prospectus does not constitute a public offer of securities in the United Arab Emirates (including the DIFC) and is not intended to be a public offer. This prospectus has not been approved by or filed with the Central Bank of the United Arab Emirates, the Securities and Commodities Authority or the DFSA.

Notice to Prospective Investors in Brazil

The offer and sale of the securities have not been and will not be registered with the Brazilian securities commission (COMISSÃO DE VALORES MOBILIÁRIOS, or “CVM”) and, therefore, will not be carried out by any means that would constitute a public offering in Brazil under CVM resolution no 160, dated 13 July 2022, as amended (“CVM resolution 160”) or unauthorized distribution under Brazilian laws and regulations. The securities may only be offered to Brazilian professional investors (as defined by applicable CVM regulation), who may only acquire the securities through a non-Brazilian account, with settlement outside Brazil in non-Brazilian currency. the trading of these securities on regulated securities markets in Brazil is prohibited.

 

297


Table of Contents

LEGAL MATTERS

The validity of the issuance of the shares of Class A common stock offered hereby will be passed upon for Venture Global, Inc. by Davis Polk & Wardwell LLP, New York, New York. Various legal matters will be passed upon for the underwriters by Skadden, Arps, Slate, Meagher & Flom LLP, New York, New York.

EXPERTS

The consolidated financial statements of Venture Global, Inc. at December 31, 2023 and 2022, and for each of the three years in the period ended December 31, 2023, appearing in this Prospectus and Registration Statement, have been audited by Ernst & Young LLP, independent registered public accounting firm, as set forth in their reports thereon appearing elsewhere herein, and are included in reliance upon such reports given on the authority of such firm as experts in accounting and auditing.

 

298


Table of Contents

WHERE YOU CAN FIND MORE INFORMATION

We have filed with the SEC a registration statement on Form S-1 under the Securities Act with respect to the Class A common stock offered hereby. This prospectus does not contain all of the information set forth in the registration statement and the exhibits and schedules thereto. For further information with respect to the company and its Class A common stock, reference is made to the registration statement and the exhibits and any schedules filed therewith. Statements contained in this prospectus as to the contents of any contract or other document referred to are not necessarily complete and in each instance, if such contract or document is filed as an exhibit, reference is made to the copy of such contract or other document filed as an exhibit to the registration statement, each statement being qualified in all respects by such reference. In addition, the SEC maintains an Internet site at www.sec.gov, from which interested persons can electronically access the registration statement, including the exhibits and any schedules thereto.

As a result of the offering, we will be required to file periodic reports and other information with the SEC. We also maintain a website at www.ventureglobal.com. Our website and the information contained therein or connected thereto shall not be deemed to be incorporated into this prospectus or the registration statement of which it forms a part and is included in this prospectus as an inactive textual reference only.

 

299


Table of Contents

INDEX TO CONSOLIDATED FINANCIAL STATEMENTS

 

     Page  
Condensed Consolidated Financial (Unaudited)   

Condensed Consolidated Balance Sheets as of September  30, 2024 and December 31, 2023

     F-2  

Condensed Consolidated Statements of Operations for the three and nine months ended September 30, 2024 and 2023

     F-3  

Condensed Consolidated Statements of Comprehensive Income (Loss) for the three and nine months ended September 30, 2024 and 2023

     F-4  

Condensed Consolidated Statements of Changes in Equity (Deficit) for the three and nine months ended September 30, 2024 and 2023

     F-5  

Condensed Consolidated Statements of Cash Flows for the three and nine months ended September 30, 2024 and 2023

     F-6  

Notes to Condensed Consolidated Financial Statements

     F-7  
Annual Consolidated Financial Statements   

Report of Independent Registered Public Accounting Firm

     F-27  

Consolidated Balance Sheets as of December 31, 2023 and 2022

     F-29  

Consolidated Statements of Operations for the years ended December  31, 2023, 2022 and 2021

     F-30  

Consolidated Statements of Comprehensive Income (Loss) for the years ended December 31, 2023, 2022 and 2021

     F-31  

Consolidated Statements of Changes in Equity (Deficit) for the years ended December 31, 2023, 2022 and 2021

     F-32  

Consolidated Statements of Cash Flows for the years ended December  31, 2023, 2022 and 2021

     F-33  

Notes to the Consolidated Financial Statements

     F-34  

Schedule I Condensed Financial Information of Parent

  

Report of Independent Registered Public Accounting Firm

     F-68  

Condensed Balance Sheets as of December 31, 2023 and 2022

     F-69  

Condensed Statements of Operations for the years ended December 31, 2023, 2022 and 2021

     F-70  

Condensed Statements of Cash Flows for the years ended December 31, 2023, 2022 and 2021

     F-71  

Notes to the Condensed Financial Information of Parent

     F-72  

 

F-1


Table of Contents

VENTURE GLOBAL, INC.

CONDENSED CONSOLIDATED BALANCE SHEETS

($ in millions, except par values and share amounts)

(unaudited)

 

     September 30,     December 31,  
     2024     2023  

ASSETS

    

Current assets

    

Cash and cash equivalents

   $ 4,562     $ 4,823  

Restricted cash

     343       520  

Accounts receivable

     96       265  

Inventory

     173       44  

Derivative assets

     124       164  

Prepaid expenses and other current assets

     82       143  
  

 

 

   

 

 

 

Total current assets

     5,380       5,959  
  

 

 

   

 

 

 

Property, plant and equipment, net

     30,685       19,439  

Right-of-use assets

     511       381  

Noncurrent restricted cash

     730       529  

Deferred financing costs

     401       464  

Noncurrent derivative assets

     839       899  

Equity method investments

     299       539  

Other noncurrent assets

     578       253  
  

 

 

   

 

 

 

TOTAL ASSETS

   $ 39,423     $ 28,463  
  

 

 

   

 

 

 

LIABILITIES AND EQUITY

    

Current liabilities

    

Accounts payable

   $ 1,170     $ 436  

Accrued and other liabilities

     1,790       1,701  

Current portion of long-term debt

     187       178  
  

 

 

   

 

 

 

Total current liabilities

     3,147       2,315  
  

 

 

   

 

 

 

Long-term debt, net including $0 and $4,944, respectively, of debt related to variable interest entities

     26,757       20,607  

Noncurrent operating lease liabilities

     457       383  

Deferred tax liabilities, net

     1,376       1,149  

Other noncurrent liabilities

     767       539  
  

 

 

   

 

 

 

Total liabilities

     32,504       24,993  
  

 

 

   

 

 

 

Contingencies (Note 13)

    

Redeemable stock of subsidiary

     1,492       1,385  

Equity

    

Venture Global, Inc. stockholders’ equity

    

Class A common stock, par value $0.01 per share (519,772 shares issued and outstanding for each period presented)

     —        —   

Additional paid in capital

     531       542  

Retained earnings

     1,673       1,228  

Accumulated other comprehensive loss

     (252     (260
  

 

 

   

 

 

 

Total Venture Global, Inc. stockholders’ equity

     1,952       1,510  

Non-controlling interests

     3,475       575  
  

 

 

   

 

 

 

Total equity

     5,427       2,085  
  

 

 

   

 

 

 

TOTAL LIABILITIES AND EQUITY

   $ 39,423     $ 28,463  
  

 

 

   

 

 

 

The accompanying notes are an integral part of these condensed consolidated financial statements.

 

F-2


Table of Contents

VENTURE GLOBAL, INC.

CONDENSED CONSOLIDATED STATEMENTS OF OPERATIONS

($ in millions, except share and per share amounts)

(unaudited)

 

     Three months ended     Nine months ended  
     September 30,     September 30,  
     2024     2023     2024     2023  

REVENUE

   $ 926     $ 1,054     $ 3,448     $ 6,265  
  

 

 

   

 

 

   

 

 

   

 

 

 

OPERATING EXPENSE

        

Cost of sales (exclusive of depreciation and amortization shown separately below)

     272       350       937       1,195  

Operating and maintenance expense

     143       126       378       279  

General and administrative expense

     77       58       224       165  

Development expense

     156       142       511       324  

Depreciation and amortization

     89       69       229       208  

Insurance recoveries, net

     —        —        —        (19
  

 

 

   

 

 

   

 

 

   

 

 

 

Total operating expense

     737       745       2,279       2,152  
  

 

 

   

 

 

   

 

 

   

 

 

 

INCOME FROM OPERATIONS

     189       309       1,169       4,113  

OTHER INCOME (EXPENSE)

        

Interest income

     53       44       187       103  

Interest expense, net

     (128     (154     (467     (448

Gain (loss) on derivatives

     (480     788       70       830  

Loss on financing transactions

     (6     (3     (14     (113
  

 

 

   

 

 

   

 

 

   

 

 

 

Total other income (expense)

     (561     675       (224     372  
  

 

 

   

 

 

   

 

 

   

 

 

 

INCOME (LOSS) BEFORE INCOME TAX EXPENSE (BENEFIT)

     (372     984       945       4,485  

Income tax expense (benefit)

     (78     203       189       868  
  

 

 

   

 

 

   

 

 

   

 

 

 

NET INCOME (LOSS)

   $ (294   $ 781     $ 756     $ 3,617  
  

 

 

   

 

 

   

 

 

   

 

 

 

Less: Net income attributable to redeemable stock of subsidiary

     37       32       107       96  

Less: Net income attributable to non-controlling interests

     15       132       44       790  

Less: Dividends on VGLNG preferred shares

     1       —        1       —   
  

 

 

   

 

 

   

 

 

   

 

 

 

NET INCOME (LOSS) ATTRIBUTABLE TO COMMON STOCKHOLDERS

   $ (347   $ 617     $ 604     $ 2,731  
  

 

 

   

 

 

   

 

 

   

 

 

 

BASIC EARNINGS (LOSS) PER SHARE

        

Net income (loss) attributable to common stockholders per share—basic

   $ (668   $ 1,402     $ 1,162     $ 6,249  

Weighted average number of shares of common stock outstanding—basic (a)

     519,772       440,080       519,772       437,043  

DILUTED EARNINGS (LOSS) PER SHARE

        

Net income (loss) attributable to common stockholders per share—diluted

   $ (668   $ 1,391     $ 1,060     $ 6,232  

Weighted average number of shares of common stock outstanding—diluted (a)

     519,772       443,661       570,022       438,237  

 

(a)

See Note 1 – General for further discussion regarding the weighted average number of shares of common stock outstanding.

The accompanying notes are an integral part of these condensed consolidated financial statements.

 

F-3


Table of Contents

VENTURE GLOBAL, INC.

CONDENSED CONSOLIDATED STATEMENTS OF COMPREHENSIVE INCOME (LOSS)

($ in millions)

(unaudited)

 

     Three months ended      Nine months ended  
     September 30,      September 30,  
      2024       2023        2024        2023   

NET INCOME (LOSS)

   $ (294   $ 781      $ 756      $ 3,617  

Other comprehensive income (loss)

          

Cash flow hedges, net

          

Change in fair value, net of income tax benefit of $0, $0, $0 and $2, respectively

     —        —         —         (8

Reclassification to earnings, net of income tax expense of $1, $0, $2 and $1, respectively

     2       1        8        3  
  

 

 

   

 

 

    

 

 

    

 

 

 

Total change in cash flow hedges, net

     2       1        8        (5
  

 

 

   

 

 

    

 

 

    

 

 

 

COMPREHENSIVE INCOME (LOSS)

   $ (292   $ 782      $ 764      $ 3,612  
  

 

 

   

 

 

    

 

 

    

 

 

 

Less: Comprehensive income attributable to redeemable stock of subsidiary

     37       32        107        96  

Less: Comprehensive income attributable to non-controlling interests

     15       132        44        788  

Less: Dividends on VGLNG preferred shares

     1       —         1        —   
  

 

 

   

 

 

    

 

 

    

 

 

 

COMPREHENSIVE INCOME (LOSS) ATTRIBUTABLE TO COMMON STOCKHOLDERS

   $ (345   $ 618      $ 612      $ 2,728  
  

 

 

   

 

 

    

 

 

    

 

 

 

The accompanying notes are an integral part of these condensed consolidated financial statements.

 

F-4


Table of Contents

VENTURE GLOBAL, INC.

CONDENSED CONSOLIDATED STATEMENTS OF CHANGES IN EQUITY (DEFICIT)

($ in millions, except share amounts)

(unaudited)

 

    Stockholders’ equity        
    Common stock     Members’
capital
    Additional
paid in
capital
    Retained
earnings
    Accumulated
other
comprehensive
loss
    Total
stockholders’
equity
    Non-controlling
interests
 
    Class A  
    Shares     Par value  

BALANCE AT DECEMBER 31, 2023

    519,772     $ —      $ —      $ 542     $ 1,228     $ (260   $ 1,510     $ 575  

Net income

    —        —        —        —        648       —        648       15  

Stock-based compensation

    —        —        —        (13     —        —        (13     —   

Distributions

    —        —        —        —        —        —        —        (15

Other comprehensive income

    —        —        —        —        —        3       3       —   
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

BALANCE AT MARCH 31, 2024

    519,772     $ —      $ —      $ 529     $ 1,876     $ (257   $ 2,148     $ 575  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income

    —        —        —        —        303       —        303       14  

Stock-based compensation

    —        —        —        (4     —        —        (4     —   

Distributions

    —        —        —        —        —        —        —        (14

Other comprehensive income

    —        —        —        —        —        3       3       —   
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

BALANCE AT JUNE 30, 2024

    519,772     $ —      $ —      $ 525     $ 2,179     $ (254   $ 2,450     $ 575  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income (loss)

    —        —        —        —        (346     —        (346     15  

Stock-based compensation

    —        —        —        6       —        —        6       —   

Dividends and distributions

    —        —        —        —        (160     —        (160     (15

Other comprehensive income

    —        —        —        —        —        2       2       —   

Issuance of VGLNG Preferred Shares, net

    —        —        —        —        —        —        —        2,900  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

BALANCE AT SEPTEMBER 30, 2024

    519,772     $ —      $ —      $ 531     $ 1,673     $ (252   $ 1,952     $ 3,475  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

 

    Stockholders’ and members’ equity (deficit)        
    Common stock     Members’
capital
    Additional
paid in
capital
    Retained
earnings
    Accumulated
other
comprehensive
loss
    Total
stockholders’
and members’
equity (deficit)
    Non-controlling
interests
 
    Class A  
    Shares     Par value  

BALANCE AT DECEMBER 31, 2022

    —      $ —      $ (690   $ —      $ 688     $ (184     (186   $ 695  

Net income

    —        —        —        —        999       —        999       396  

Stock-based compensation

    —        —        —        —        —        —        —        8  

Distributions

    —        —        —        —        (2     —        (2     —   

Other comprehensive loss

    —        —        —        —        —        (5     (5     (2

Purchase of non-controlling interests

    —        —        (168     —        —        (4     (172     (68
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

BALANCE AT MARCH 31, 2023

    —      $ —      $ (858   $ —      $ 1,685     $ (193   $ 634     $
 
 
1,029
 
 
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income

    —        —        —        —        1,115       —        1,115       262  

Stock-based compensation

    —        —        —        —        —        —        —        2  

Distributions

    —        —        —        —        (2     —        (2     —   

Other comprehensive income

    —        —        —        —        —        1       1       —   

Purchase of non-controlling interests

    —        —        (923     —        —        (27     (950     (374
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

BALANCE AT JUNE 30, 2023

    —      $ —      $ (1,781   $ —      $ 2,798     $ (219   $ 798     $ 919  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income

    —        —        —        —        617       —        617       132  

Stock-based compensation

    —        —        —        —        —        —        —        7  

Dividends and distributions

    —        —        —        —        (144     —        (144     (14

Other comprehensive income

    —        —        —        —        —        1       1       —   

Conversion of Members’ capital to Common stock

    435,500       —        1,781       171       (1,992     —        (40     —   

Purchase of non-controlling interests

    84,272       —        —        512       —        (43     469       (469
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

BALANCE AT SEPTEMBER 30, 2023

    519,772     $ —      $ —      $ 683     $ 1,279     $ (261   $ 1,701     $ 575  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

The accompanying notes are an integral part of these condensed consolidated financial statements.

 

F-5


Table of Contents

VENTURE GLOBAL, INC.

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS

($ in millions)

(unaudited)

 

     Nine months ended  
     September 30,  
     2024     2023  

OPERATING ACTIVITIES

    

Net income

   $ 756     $ 3,617  

Adjustments to reconcile net income to net cash from operating activities:

    

Gain on derivatives, net

     (70     (830

Net cash from settlement of derivatives

     160       170  

Loss on financing transactions

     14       112  

Deferred taxes

     186       742  

Non-cash interest expense

     55       71  

Depreciation and amortization

     229       208  

Stock-based compensation

     18       21  

Changes in operating assets and liabilities:

    

Accounts receivable

     169       63  

Inventory

     (129     (12

Prepaid expenses and other current assets

     18       (26

Accounts payable and accrued liabilities

     51       (138

Other, net

     19       (41
  

 

 

   

 

 

 

Net cash from operating activities

     1,476       3,957  
  

 

 

   

 

 

 

INVESTING ACTIVITIES

    

Purchases of property, plant and equipment

     (10,058     (4,538

Purchase of equity method investments

     (78     (436

Other investing activities

     (300     (70
  

 

 

   

 

 

 

Net cash used by investing activities

     (10,436     (5,044
  

 

 

   

 

 

 

FINANCING ACTIVITIES

    

Proceeds from project credit facilities

     5,410       1,860  

Proceeds from issuance of VGLNG Preferred Shares

     3,000       —   

Repayment of debt

     (859     (5,088

Proceeds from issuance of debt

     1,584       7,280  

Purchase of non-controlling interests

     —        (1,564

Payments of financing and issuance costs

     (95     (458

Other financing activities

     (317     (237
  

 

 

   

 

 

 

Net cash from financing activities

     8,723       1,793  
  

 

 

   

 

 

 

Net increase (decrease) in cash, cash equivalents and restricted cash

     (237     706  

Cash, cash equivalents and restricted cash at beginning of period

     5,872       2,412  
  

 

 

   

 

 

 

CASH, CASH EQUIVALENTS AND RESTRICTED CASH AT END OF PERIOD

   $ 5,635     $ 3,118  
  

 

 

   

 

 

 

The accompanying notes are an integral part of these condensed consolidated financial statements.

 

F-6


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

Note 1 – General

Interim financial presentation

The accompanying unaudited condensed consolidated financial statements have been prepared in accordance with generally accepted accounting principles in the United States of America (“GAAP”) for interim financial information. Accordingly, they do not include all of the information and notes required by GAAP for annual financial statements. In the opinion of management, all adjustments, consisting only of normal recurring adjustments considered necessary for fair presentation, have been included. Interim results are not necessarily indicative of results for a full year. The accompanying condensed consolidated financial statements are unaudited and should be read in conjunction with the audited consolidated financial statements and notes thereto for the year ended December 31, 2023 (the “2023 annual financial statements”). Refer to the 2023 annual financial statements for capitalized terms not defined within these condensed consolidated financial statements.

The Company

Venture Global, Inc. (“Venture Global”) is a Delaware corporation formed by the managing members of Venture Global Partners II, LLC (“VG Partners”) on September 19, 2023. As used in these condensed consolidated financial statements, unless the context otherwise requires, references to the “Company,” “we,” “us,” and “our” refer to Venture Global and its consolidated subsidiaries.

Regulatory approvals

The construction and operation of our liquefied natural gas (“LNG”) projects are subject to extensive regulation under federal, state and local statutes, rules, regulations and laws. These laws require us to engage in consultations with appropriate federal, state and local agencies and obtain and maintain applicable permits and other authorizations. In June 2024, Venture Global CP2 LNG, LLC and Venture Global CP Express, LLC (together, the “CP2 LNG Project”), received authorization from the Federal Energy Regulatory Commission (“FERC”) to site, construct and operate the CP2 LNG Project. Project opponents, including the Sierra Club, have challenged FERC’s authorization of the CP2 LNG Project in an appeal filed with the U.S. Court of Appeals for the D.C. Circuit. The Company will continue to monitor the progress of the appeal process.

The CP2 LNG Project has not yet obtained all other applicable permits and authorizations for the project, including the authorization from the Department of Energy (“DOE”) to export natural gas to non-free trade agreement (“non-FTA”) nations, as further discussed below.

In January 2024, the Biden administration announced a temporary pause on new authorizations of natural gas exports to non-FTA nations while the DOE conducts studies to update its analyses regarding whether the exports are “not inconsistent with the public interest” to consider the latest available information regarding macro-economic impacts, domestic energy prices, potential greenhouse gas, climate or other environmental effects, and national security implications. On July 1, 2024, a Federal District Judge in Louisiana granted a motion for preliminary injunction by numerous states, holding the DOE pause appears to be unlawful and staying the pause in its entirety. In August 2024, the DOE appealed the decision of the Federal District Judge with the United States Court of Appeals for the Fifth Circuit.

Basis of presentation and consolidation

The condensed consolidated financial statements include the accounts of Venture Global, Inc. and its controlled subsidiaries. All intercompany transactions and balances have been eliminated in consolidation. In September

 

F-7


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

2023, Venture Global was party to certain reorganization transactions (the “Reorganization Transactions”) whereby Venture Global Partners, LLC (“Legacy VG Partners”), a then wholly-owned subsidiary of VG Partners merged with and into Venture Global (the “2023 Merger”). See Note 14 – Equity for further discussion. The financial results and other information included in these condensed consolidated financial statements for periods prior to the Reorganization Transactions are reflective of Legacy VG Partners and have been applied on a retrospective basis, except for earnings per share. Historical earnings per share was calculated based on the one-for-one exchange ratio of Venture Global’s Class A common stock issued to VG Partners in exchange for 100% of the Legacy VG Partners equity interest in connection with the 2023 Merger.

Use of estimates

The preparation of condensed consolidated financial statements in conformity with GAAP requires management to make estimates and assumptions that affect the reported amounts in the condensed consolidated financial statements and in the accompanying notes. While management believes that the estimates and assumptions used in the preparation of the condensed consolidated financial statements are appropriate, actual results could differ from those estimates.

Note 2 – Restricted Cash

The following table summarizes the components of restricted cash (in millions):

 

     September 30,      December 31,  
     2024      2023  

Current restricted cash

     

Calcasieu Pass Project cash reserves (a)

   $ 342      $ 520  

Other

     1        —   
  

 

 

    

 

 

 

Total current restricted cash

   $ 343      $ 520  
  

 

 

    

 

 

 

Noncurrent restricted cash

     

Plaquemines Project construction (b)

   $ 467      $ 310  

Calcasieu Pass Project cash reserves (c)

     225        219  

Other (d)

     38        —   
  

 

 

    

 

 

 

Total noncurrent restricted cash

   $ 730      $ 529  
  

 

 

    

 

 

 

 

(a)

Associated with pre-commercial operations LNG sales and restricted to use at the Calcasieu Pass Project.

(b)

Restricted to the payment of construction and commissioning costs for the Plaquemines Project.

(c)

Primarily associated with debt service reserves for the Calcasieu Pass Project.

(d)

Restricted to the payment of equipment costs for a development project.

 

F-8


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

The following table provides a reconciliation of cash, cash equivalents and restricted cash reported within the

Condensed Consolidated Balance Sheets to the Condensed Consolidated Statements of Cash Flows (in millions):

 

     September 30,      December 31,  
     2024      2023  

Cash and cash equivalents

   $ 4,562      $ 4,823  

Current restricted cash

     343        520  

Noncurrent restricted cash

     730        529  
  

 

 

    

 

 

 

Cash, cash equivalents and restricted cash per the Condensed Consolidated Statements of Cash Flows

   $ 5,635      $ 5,872  
  

 

 

    

 

 

 

Note 3 – Revenue from Contracts with Customers

The following table summarizes the disaggregation of revenue earned from contracts with customers (in millions):

 

     Three months ended      Nine months ended  
     September 30,      September 30,  
      2024        2023       2024      2023  

LNG revenue

   $ 921      $ 1,049      $ 3,431      $ 6,249  

Other revenue

     5        5        17        16  
  

 

 

    

 

 

    

 

 

    

 

 

 

Total revenue

   $ 926      $ 1,054      $ 3,448      $ 6,265  
  

 

 

    

 

 

    

 

 

    

 

 

 

LNG produced prior to an LNG project or phase thereof reaching commercial operations date (“COD”) is sold under short-term sales agreements (“Early Cargo Sales Agreements”), at the prevailing market prices when executed. COD has not yet occurred for any of our LNG projects or phases thereof, and accordingly, LNG revenue recognized during the three and nine months ended September 30, 2024 and 2023, was earned under Early Cargo Sales Agreements.

Transaction price allocated to future performance obligations

Because many of our sales contracts have long-term durations, we are contractually entitled to significant future consideration which we have not yet recognized as revenue. The following table discloses the aggregate amount of the transaction price, including variable consideration, that is allocated to performance obligations that have not yet been satisfied, excluding all performance obligations that are part of contracts that have an expected duration of one year or less (dollar amounts in billions):

 

     September 30, 2024  
     Unsatisfied
transaction price (a)
     Weighted average
recognition timing
(in years)
 

LNG revenue

   $ 180.4        20 years  

 

(a)

A portion of the transaction price is based on the forecasted Henry Hub index as of period end.

Significant judgments were made when estimating the transaction price allocated to future performance obligations. These include the best estimate of when our respective projects will reach their COD and their

 

F-9


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

post-COD sales contracts commence, which we currently expect to occur in early 2025 for our Calcasieu Pass Project and in 2026 and 2027 for the first and second phases of our Plaquemines Project, respectively, and the most likely amount of variable consideration to which we expect to be entitled upon the resolution of certain ongoing disputes with customers. These disputes are with various Calcasieu Pass post-COD term sales and purchase agreements (“SPAs”) customers who are asserting that the Calcasieu Pass Project is delayed in declaring COD under the respective SPAs. These disputes are subject to aggregate liability limitations of $1.6 billion under the SPAs. Certain of our customers are also disputing whether the liability limitations in our SPAs are applicable, and therefore are claiming damages in excess of the liability limitations. Our estimates of variable consideration exclude decreases to the transaction price for these contingent penalties based on our best estimate of the most likely outcome of these disputes. We expect this variability to be resolved in 2025 and 2026 upon the conclusion of various arbitration proceedings.

Note 4 – Inventory

The following table summarizes the components of inventory (in millions):

 

     September 30,      December 31,  
     2024      2023  

Spare parts and materials

   $ 113      $ 39  

LNG

     24        5  

LNG in-transit

     28        —   

Other

     8        —   
  

 

 

    

 

 

 

Total inventory

   $ 173      $ 44  
  

 

 

    

 

 

 

Note 5 – Property, Plant and Equipment

The following table presents the components of property, plant and equipment, net (in millions) and their estimated useful lives (in years):

 

     Estimated useful life      September 30,
2024
     December 31,
2023
 

Terminal and interconnected pipeline facilities

     7-30      $ 7,234      $ 7,050  

Construction in progress

     N/A        18,585        9,000  

Advanced equipment and construction payments

     N/A        4,369        3,617  

LNG tankers

     25        629        —   

Buildings (a)

     35        118        —   

Land (a)

     N/A        44        26  

Other (b)

     2-23        399        198  
     

 

 

    

 

 

 

Total property, plant and equipment at cost

        31,378        19,891  

Accumulated depreciation and amortization

        (693      (452
     

 

 

    

 

 

 

Total property, plant and equipment, net (c)

      $ 30,685      $ 19,439  
     

 

 

    

 

 

 

 

(a)

Subject to an $84 million mortgage with a first priority interest in the property.

 

F-10


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

(b)

Includes finance lease assets. See Note 6 – Leases for further discussion.

(c)

Includes $677 million and $10.6 billion of Property, plant and equipment restricted to use at wholly-owned consolidated variable interest entities (“VIEs”) as of September 30, 2024 and December 31, 2023, respectively.

In July 2024, the Company acquired the remaining equity ownership interests in Astra 5 Limited (“Astra 5”) and Astra 8 Limited (“Astra 8,” and together with Astra 5, the “Astra Companies”). The purchase of the Astra Companies was recognized prospectively as an asset acquisition of two LNG tankers, Venture Gator and Venture Bayou. See Note 7 – Equity Method Investments for further discussion.

The following table presents depreciation expense recognized on the Company’s Condensed Consolidated Statements of Operations (in millions):

 

     Three months ended      Nine months ended  
     September 30,      September 30,  
     2024      2023       2024        2023   

Depreciation expense

   $ 87      $ 69      $ 224      $ 205  

Note 6 – Leases

The Company’s operating leases consist primarily of leased land, LNG tankers, and office space and facilities. The Company’s finance leases consist primarily of leased marine vessels and a bridge.

The following table presents the line item classification of the Company’s right-of-use assets and lease liabilities on our Condensed Consolidated Balance Sheets (in millions):

 

    

Line item

   September 30,
2024
     December 31,
2023
 

Right-of-use assets - operating

   Right-of-use assets    $ 511      $ 381  

Right-of-use assets - finance

   Property, plant and equipment, net      279        101  
     

 

 

    

 

 

 

Total right-of-use assets

      $ 790      $ 482  
     

 

 

    

 

 

 

Current operating lease liabilities

   Accrued and other liabilities    $ 61      $ 13  

Current finance lease liabilities

   Accrued and other liabilities      10        13  

Noncurrent operating lease liabilities

   Noncurrent operating lease liabilities      457        383  

Noncurrent finance lease liabilities

   Other noncurrent liabilities      250        75  
     

 

 

    

 

 

 

Total lease liabilities

      $ 778      $ 484  
     

 

 

    

 

 

 

 

F-11


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

The following table presents the line item classification of the Company’s lease costs (in millions):

 

          Three months ended      Nine months ended  
          September 30,      September 30,  
    

Line item

   2024      2023      2024      2023  

Operating lease cost

   Operating expense (a)    $ 28      $ 13      $ 69      $ 34  

Finance lease cost

              

Amortization of right-of-use assets

   Depreciation and amortization and Property, plant and equipment, net      3        3        9        8  

Interest on lease liabilities

   Interest expense, net and Property, plant and equipment, net      5        1        11        4  
     

 

 

    

 

 

    

 

 

    

 

 

 

Total lease cost

      $ 36      $ 17      $ 89      $ 46  
     

 

 

    

 

 

    

 

 

    

 

 

 

 

(a)

Presented in the various line items within operating expenses, consistent with the nature of the asset under lease.

Note 7 – Equity Method Investments

The following table presents the Company’s equity method investment ownership interests and carrying values (dollar amounts in millions):

 

     September 30, 2024      December 31, 2023  

Equity method investment (a)

   Ownership
interest
    Carrying
value (b)
     Ownership
interest
    Carrying
value
 

Kagami 1

     39   $ 160        19   $ 110  

Kagami 2

     29     139        19     110  

Astra 5

     100     —         40     159  

Astra 8

     100     —         40     160  
    

 

 

      

 

 

 

Total

     $ 299        $ 539  
    

 

 

      

 

 

 

 

(a)

These companies are VIEs in which the Company is not the primary beneficiary since it lacks the power to make significant decisions.

(b)

Excludes the carrying value of entities that are consolidated as of September 30, 2024. See Note 5 – Property, Plant and Equipment for further discussion.

Astra Companies

In July 2024, the Company completed the acquisition of the equity ownership interests in the Astra Companies through a series of transactions for a total purchase price of $560 million. See Note 5 – Property, Plant and Equipment for further discussion.

 

F-12


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

Kagami Companies

In 2023, the Company began acquiring equity interests in Project Kagami 1 Limited (“Kagami 1”) and Project Kagami 2 Limited (“Kagami 2,” and together with Kagami 1, the “Kagami Companies”). The Kagami Companies will each purchase one LNG tanker, which are expected to be delivered in 2025. The Company has future commitments to increase its investment in the Kagami Companies by $272 million to fund construction of the LNG tankers, which are subject to conditions precedent that have not yet been satisfied.

Note 8 – Accrued and Other Liabilities

Components of accrued and other liabilities included (in millions):

 

     September 30,      December 31,  
     2024      2023  

Accrued construction and equipment costs

   $ 836      $ 1,012  

Accrued interest

     278        230  

Accrued natural gas purchases

     114        164  

Accrued compensation

     159        134  

Accrued dividends and distributions

     135        15  

Other

     268        146  
  

 

 

    

 

 

 

Total accrued and other liabilities

   $ 1,790      $ 1,701  
  

 

 

    

 

 

 

 

F-13


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

Note 9 – Debt

The following table summarizes the Company’s outstanding debt (dollar amounts in millions):

 

     Maturity      Interest rate     September 30,
2024
    December 31,
2023
 

Fixed rate:

         

VGLNG 2028 Notes

     June 1, 2028        8.125   $ 2,250     $ 2,250  

VGLNG 2029 Notes (a)

     February 1, 2029        9.500     3,000       3,000  

VGLNG 2030 Notes

     January 15, 2030        7.000     1,500       —   

VGLNG 2031 Notes

     June 1, 2031        8.375     2,250       2,250  

VGLNG 2032 Notes (b)

     February 1, 2032        9.875     2,000       2,000  

Calcasieu Pass 2029 Notes

     August 15, 2029        3.875     1,250       1,250  

Calcasieu Pass 2030 Notes

     January 15, 2030        6.250     1,000       1,000  

Calcasieu Pass 2031 Notes

     August 15, 2031        4.125     1,250       1,250  

Calcasieu Pass 2033 Notes

     November 1, 2033        3.875     1,250       1,250  

Other fixed rate debt

     September 5, 2029        7.600     84       —   

Variable rate:

         

Calcasieu Pass Construction Term Loan

          1,042       1,174  

PL Holdings Credit Facility (c)

          —        727  

Plaquemines Construction Term Loan

          10,354       4,944  
       

 

 

   

 

 

 

Total outstanding debt

          27,230       21,095  
       

 

 

   

 

 

 

Less: Unamortized debt discount, premium and issuance costs

          (286     (310
       

 

 

   

 

 

 

Total outstanding debt, net

          26,944       20,785  

Less: Current portion of long-term debt

          (187     (178
       

 

 

   

 

 

 

Total long-term debt, net

        $ 26,757     $ 20,607  
       

 

 

   

 

 

 

 

(a)

Issued in October and November 2023 at 100.167% of par.

(b)

Issued in October and November 2023 at 99.661% of par.

(c)

In July 2024, the Company fully prepaid the remaining principal outstanding under the PL Holdings Credit Facility.

VGLNG Senior Secured Notes

In July 2024, the Company’s subsidiary, Venture Global LNG, Inc., (“VGLNG”) issued a series of 7.000% senior secured notes due 2030 in an aggregate principal amount of $1.5 billion (the “VGLNG 2030 Notes”). The VGLNG 2028 Notes, VGLNG 2029 Notes, VGLNG 2030 Notes, VGLNG 2031 Notes, and VGLNG 2032 Notes are collectively referred to as the “VGLNG Senior Secured Notes”. The VGLNG Senior Secured Notes are secured on a pari passu basis by a first-priority security interest in substantially all of the existing and future assets of VGLNG and the future guarantors, if any. In addition, VGLNG has pledged its membership interests in certain material direct subsidiaries as collateral to secure its obligations under the VGLNG Senior Secured Notes. VGLNG may redeem all or part of the VGLNG Senior Secured Notes at specified prices set forth in the respective governing indenture agreements, plus accrued interest, if any, as of the date of the redemption.

 

F-14


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

Calcasieu Pass Senior Secured Notes

The Calcasieu Pass 2029 Notes, Calcasieu Pass 2030 Notes, Calcasieu Pass 2031 Notes, and Calcasieu Pass 2033 Notes are collectively referred to as the “Calcasieu Pass Senior Secured Notes”. The obligations of Calcasieu Pass under the Calcasieu Pass Senior Secured Notes are guaranteed by TransCameron and secured on a pari passu basis by a first-priority security interest in the assets that secure the Calcasieu Pass Credit Facility. Calcasieu Pass may redeem all or part of the Calcasieu Pass Senior Secured Notes at specified prices set forth in the respective governing indenture agreements, plus accrued interest, if any, as of the date of the redemption.

Credit Facilities

Below is a summary of the Company’s committed credit facilities outstanding as of September 30, 2024 (in millions):

 

    Calcasieu Pass Credit Facility (a)     Plaquemines Credit Facility (b)  
    Calcasieu Pass
Construction
Term Loan
    Calcasieu Pass
Working Capital
Facility
    Plaquemines
Construction
Term Loan
    Plaquemines
Working Capital
Facility
 

Original facility size

  $ 5,477     $ 300     $ 8,459     $ 1,100  

Incremental commitments

    —        255       4,489       1,000  

Less:

       

Outstanding balances

    1,042       —        10,354       —   

Commitments prepaid or terminated

    4,435       —        —        —   

Letters of credit issued

    —        254       —        1,181  
 

 

 

   

 

 

   

 

 

   

 

 

 

Available commitments

  $ —      $ 301     $ 2,594     $ 919  
 

 

 

   

 

 

   

 

 

   

 

 

 

Priority ranking

    Senior secured       Senior secured       Senior secured       Senior secured  

Maturity date

    August 19, 2026       August 19, 2026       May 25, 2029       May 25, 2029  

 

(a)

The obligations of Calcasieu Pass as the borrower are guaranteed by TransCameron and secured by a first-priority lien on substantially all of the assets of Calcasieu Pass and TransCameron, as well as all of the membership interests in those companies.

(b)

The obligations of Plaquemines as the borrower are guaranteed by Gator Express and secured by a first-priority lien on substantially all of the assets of Plaquemines and Gator Express, as well as all of the membership interests in those companies.

 

F-15


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

Interest expense on debt

The following table presents the total interest expense incurred on the Company’s debt and other instruments (in millions):

 

     Three months ended
September 30,
     Nine months ended
September 30,
 
      2024        2023       2024      2023  

Stated interest

   $ 503      $ 254      $ 1,375      $ 675  

Amortization of debt discounts, premiums and issuance costs

     34        36        106        102  

Other interest and fees

     15        31        55        89  
  

 

 

    

 

 

    

 

 

    

 

 

 

Total interest cost

     552        321        1,536        866  

Capitalized interest

     (424      (167      (1,069      (418
  

 

 

    

 

 

    

 

 

    

 

 

 

Total interest expense, net

   $ 128      $ 154      $ 467      $ 448  
  

 

 

    

 

 

    

 

 

    

 

 

 

Note 10 – Derivatives

Interest rate swaps

The Company has entered into interest rate swaps to mitigate its exposure to variability in interest payments associated with certain variable rate debt. We do not utilize derivatives for trading or speculative purposes. None of the Company’s interest rate swaps have been designated as cash flow hedges as of September 30, 2024 or December 31, 2023.

The following table summarizes the Company’s outstanding interest rate swaps (dollar amounts in millions):

 

                          Outstanding notional  

Debt instrument

  Latest
maturity
   

Receive
variable rate

  Pay
fixed rate (c)
    Maximum
notional
    September 30,
2024
    December 31,
2023
 

Plaquemines Credit Facility

    2046  (a)    Compounding SOFR     2.49   $ 10,204     $ 7,555     $ 5,059  

Calcasieu Pass Credit Facility

    2036  (b)    Compounding SOFR     2.55     1,013       1,013       1,142  
       

 

 

   

 

 

   

 

 

 
        $ 11,217     $ 8,568     $ 6,201  
       

 

 

   

 

 

   

 

 

 

 

(a)

Subject to mandatory early termination provisions under which certain interest rate swaps will settle at their fair values in May 2029.

(b)

Subject to mandatory early termination provisions under which certain interest rate swaps will settle at their fair values in August 2026.

(c)

Represents a weighted-average fixed rate based on the maximum notional.

 

F-16


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

The following table summarizes the fair value (in millions) and classification of the Company’s derivatives on the Condensed Consolidated Balance Sheets:

 

          September 30,      December 31,  
    

Balance sheet location

   2024      2023  

Assets

        

Interest rate swaps

   Derivative assets    $ 124      $ 164  

Interest rate swaps

   Noncurrent derivative assets      839        899  
     

 

 

    

 

 

 

Total assets

      $ 963      $ 1,063  
     

 

 

    

 

 

 

Liabilities

        

Interest rate swaps

   Accrued and other liabilities    $ 1      $ 1  

Interest rate swaps

   Other noncurrent liabilities      5        6  
     

 

 

    

 

 

 

Total liabilities

      $ 6      $ 7  
     

 

 

    

 

 

 

The following table presents the pre-tax effects of the Company’s derivative instruments recognized in Accumulated other comprehensive loss (“AOCL”) and earnings (in millions):

 

          Three months ended      Nine months ended  
          September 30,      September 30,  
    

Line item

    2024       2023       2024        2023   

Designated as hedging instruments Loss recognized in AOCL

             

Interest rate swaps

   Change in fair value    $ —      $ —       $ —       $ (10

Reclassifications of losses from AOCL into earnings

             

Interest rate swaps

   Depreciation and amortization      1       —         2        1  

Interest rate swaps

   Interest expense, net      2       1        8        3  

Not designated as hedging instruments — recognized in earnings

             

Interest rate swaps

   Gain (loss) on derivatives      (480     788        70        830  

Approximately $14 million is expected to be reclassified from AOCL as a reduction to earnings within the next

twelve months.

The following table presents the gross and net fair value of the Company’s outstanding interest rate swaps (in

millions):

 

     September 30, 2024      December 31, 2023  
     Gross
balance
     Balance subject
to netting
     Net
balance
     Gross
balance
     Balance subject
to netting
     Net balance  

Derivative assets

   $ 963      $ —       $ 963      $ 1,063      $ —       $ 1,063  

Derivative liabilities

     6        —         6        7        —         7  

 

F-17


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

Credit-risk related contingent features

The interest rate swap agreements contain cross default provisions whereby if the Company were to default on certain indebtedness, it could also be declared in default on its derivative obligations and may be required to net settle the outstanding derivative liability positions with its counterparties. As of September 30, 2024, the Company had not posted any collateral related to these agreements and was not in breach of any agreement provisions. The aggregate fair value of our derivative instruments with credit-risk related contingent features in a net liability position was $6 million as of September 30, 2024.

Note 11 – Fair Value Measurements

The following table presents the Company’s financial assets and liabilities measured at fair value on a recurring basis and indicates their levels within the fair value hierarchy (in millions):

 

     September 30, 2024      December 31, 2023  
     Level 1      Level 2      Total      Level 1      Level 2      Total  

Assets

                 

Money market funds (a)

   $ 1,284      $ —       $ 1,284      $ 3,391      $ —       $ 3,391  

Interest rate swaps (b)

     —         963        963        —         1,063        1,063  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ 1,284      $ 963      $ 2,247      $ 3,391      $ 1,063      $ 4,454  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Liabilities

                 

Interest rate swaps (c)

   $ —       $ 6      $ 6      $ —       $ 7      $ 7  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ —       $ 6      $ 6      $ —       $ 7      $ 7  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

 

(a)

Included in Cash and cash equivalents on the Condensed Consolidated Balance Sheets.

(b)

Included in Derivative assets and Noncurrent derivative assets on the Condensed Consolidated Balance Sheets.

(c)

Included in Accrued and other liabilities and Other noncurrent liabilities on the Condensed Consolidated Balance Sheets.

Interest rate swaps

The fair values of the Company’s interest rate swaps are classified as Level 2 and determined using a discounted cash flow method that incorporates observable inputs. The fair value calculation includes a credit valuation adjustment and forward interest rate curves for the same periods of the future maturity dates of the interest rate swaps. For further discussion, see Note 10 – Derivatives.

Other financial instruments

The following table presents the fair value of the Company’s outstanding debt instruments in the Condensed Consolidated Balance Sheets (in millions):

 

            September 30,      December 31,  
     Level      2024      2023  

Fixed rate debt

     1      $ 16,372      $ 14,098  

Variable and other fixed rate debt (a)

     2        11,480        6,845  

 

(a)

Carrying value approximates estimated fair value.

 

F-18


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

Note 12 – Income Taxes

Our provision for income taxes is based on an estimated annual effective tax rate, plus discrete items. Our effective tax rate was 21.0% and 20.0% for the three and nine months ended September 30, 2024, respectively, and was lower than the statutory income tax rate due to a combination of factors including guaranteed payments to non-controlling interests and non-deductible expenses.

Our effective tax rate was 20.6% and 19.4% for the three and nine months ended September 30, 2023, respectively, and was lower than the statutory income tax rate due to a combination of factors including a deduction related to foreign-derived intangible income (“FDII”), guaranteed payments to non-controlling interests, and non-deductible expenses.

VGLNG and Calcasieu Pass Holdings, LLC (“CP Holdings”), subsidiaries of the Company, are currently under exam by the Internal Revenue Service for the 2022 tax year.

Note 13 – Contingencies

Litigation

The Company is involved in certain claims, suits, and legal proceedings in the normal course of business. The Company accrues for litigation and claims when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. There can be no assurance that these accrued liabilities will be adequate to cover all existing and future claims or that we will have the liquidity to pay such claims as they arise.

Where no accrued liability has been recognized, it is reasonably possible that some matters could be decided unfavorably to the Company. This could require the Company to pay damages or make expenditures in amounts that could be material but could not be estimated as of September 30, 2024.

In October 2024, the Company received a final award related to arbitration with one of its construction contractors regarding certain disputes under a construction contract. As a result of this final award, the Company recognized $162 million as accrued Property, plant and equipment on the Condensed Consolidated Balance Sheet as of September 30, 2024. See Note 3 – Revenue from Contracts with Customers, for discussion of certain disputes with customers.

Note 14 – Equity

Dividends

In September 2024, the Company’s Board of Directors declared the payment of cash dividends to the Company’s Class A common stockholders in an aggregate amount of $160 million that, subject to applicable law, will be paid on a pro rata basis in four equal installments of $40 million over four consecutive calendar quarters on the last business day of each such calendar quarter, commencing on September 30, 2024. Cash paid for dividends is recognized as Other financing activities in the Condensed Consolidated Statements of Cash Flows and accrued dividends are recognized as Accrued and other liabilities in the Condensed Consolidated Balance Sheets. See Note 8 – Accrued and Other Liabilities, for further discussion.

Reorganization Transaction

In September 2023, as part of the 2023 Merger, when VG Partners was merged with and into Venture Global, VG Partners received 435,500 shares of Venture Global’s Class A common stock in exchange for 100% of its equity interests in Legacy VG Partners. In connection with the Reorganization Transactions, the non-controlling VGLNG shareholders, holding 84,272 shares of VGLNG’s issued and outstanding Series C common stock,

 

F-19


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

received 84,272 shares of Class A common stock of Venture Global, in a one-for-one exchange for their shares of VGLNG (the “NCI Acquisition”). All shares of Series A, Series B and Series C common stock of VGLNG were retired upon completion of the Reorganization Transactions in September 2023. No cash was exchanged as part of the Reorganization Transactions and Venture Global incurred $40 million of third-party transaction costs in connection with its formation and the issuance of its shares of Class A common stock.

Authorized shares

The Company has authorized for issuance 1,000,000 shares of preferred stock, 1,000,000 shares of Class A common stock and 1,000,000 of Class B common stock as of September 30, 2024 and December 31, 2023.

Note 15 – Non-Controlling Interests

VGLNG Preferred Shares

In September 2024, VGLNG issued 3,000,000 shares of 9.00% Series A Fixed-Rate Reset Cumulative Redeemable Perpetual Preferred Stock (the “VGLNG Preferred Shares”) for gross proceeds of $3.0 billion. The Company incurred $100 million of costs in connection with the issuance which were recognized as a reduction to the offering proceeds.

The VGLNG Preferred Shares are not convertible or exchangeable for any other securities or property and have no voting rights, aside from those required by law. The VGLNG Preferred Shares are perpetual and have no maturity date. The VGLNG Preferred Shares may only be redeemed at the option of the Company, in whole or in part, on one or more occasions at any time after September 30, 2029 (the “First Reset Date”) and in certain other circumstances prior to the First Reset Date. The VGLNG Preferred Shares have a liquidation preference of $1,000 per share, plus accumulated but unpaid dividends.

The annual dividend rate on the VGLNG Preferred Shares is 9.00% from the issuance date to, but excluding, the First Reset Date. On and after the First Reset Date, the dividend rate on the VGLNG Preferred Shares will equal the five-year U.S. Treasury rate as of the most recent reset dividend determination date (subject to a floor of 1.00%), plus a spread of 5.44% per annum. Cumulative cash dividends on the VGLNG Preferred Shares are payable semiannually, in arrears commencing on March 30, 2025, when, and if, declared by the VGLNG Board of Directors. As of September 30, 2024, the accumulated but undeclared dividends were $1 million, or $0.25 per-share.

VGLNG common stock

During the nine months ended September 30, 2023, and prior to the Reorganization Transactions, VGLNG entered into agreements to repurchase 5,000 shares of its Series B and 81,896 shares of its Series C common stock for $1.6 billion. To reflect this change in ownership interest, the Company recognized decreases of $1.2 billion and $0.4 billion in stockholders’ and members’ equity and non-controlling interests, respectively.

 

F-20


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

CP Holdings

CP Holdings, an indirect controlled subsidiary of the Company, issued Convertible Preferred Units, which represent third-party ownership in the net assets of CP Holdings. The following table summarizes the changes in the Convertible Preferred Units (in millions):

 

     Three months ended  
     September 30,  
      2024        2023   

Beginning balance as of July 1

   $ 575      $ 575  

Net income attributable to non-controlling interests

     15        14  

Distributions

     (15      (14
  

 

 

    

 

 

 

Ending balance as of September 30

   $ 575      $ 575  
  

 

 

    

 

 

 

 

     Nine months ended  
     September 30,  
      2024        2023   

Beginning balance as of January 1

   $ 575      $ 547  

Net income attributable to non-controlling interests

     44        42  

Distributions

     (44      (14
  

 

 

    

 

 

 

Ending balance as of September 30

   $ 575      $ 575  
  

 

 

    

 

 

 

Note 16 – Redeemable Stock of Subsidiary

The following table summarizes the changes in Redeemable stock of subsidiary on the Condensed Consolidated Balance Sheets (in millions):

 

     Three months ended  
     September 30,  
     2024      2023  

Beginning balance as of July 1

   $ 1,455      $ 1,319  

Paid-in-kind distributions (a)

     37        32  
  

 

 

    

 

 

 

Ending balance as of September 30

   $ 1,492      $ 1,351  
  

 

 

    

 

 

 

 

     Nine months ended  
     September 30,  
     2024      2023  

Beginning balance as of January 1

   $ 1,385      $ 1,255  

Paid-in-kind distributions (a)

     107        96  
  

 

 

    

 

 

 

Ending balance as of September 30

   $ 1,492      $ 1,351  
  

 

 

    

 

 

 

 

(a)

Presented as Net income attributable to redeemable stock of subsidiary on the Condensed Consolidated Statements of Operations.

 

F-21


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

Note 17 – Earnings (Loss) per Share

The following table sets forth the computation of net income (loss) per share attributable to the Company’s Class A common stock outstanding (in millions, except share and per share amounts):

 

     Three months ended      Nine months ended  
     September 30,      September 30,  
     2024      2023      2024      2023  

Net income (loss)

   $ (294    $ 781      $ 756      $ 3,617  

Less: Net income attributable to redeemable stock of subsidiary

     37        32        107        96  

Less: Net income attributable to non-controlling interests

     15        132        44        790  

Less: Dividends on VGLNG preferred shares

     1        —         1        —   
  

 

 

    

 

 

    

 

 

    

 

 

 

Net income (loss) attributable to common stockholders

   $ (347    $ 617      $ 604      $ 2,731  
  

 

 

    

 

 

    

 

 

    

 

 

 

Weighted average shares of common stock outstanding

           

Basic

     519,772        440,080        519,772        437,043  

Dilutive stock options outstanding

     —         3,581        50,250        1,194  
  

 

 

    

 

 

    

 

 

    

 

 

 

Diluted

     519,772        443,661        570,022        438,237  
  

 

 

    

 

 

    

 

 

    

 

 

 

Net income (loss) attributable to common stockholders per share—basic

   $ (668    $ 1,402      $ 1,162      $ 6,249  

Net income (loss) attributable to common stockholders per share—diluted

   $ (668    $ 1,391      $ 1,060      $ 6,232  

Stock options to purchase 49,415 and 200 shares of the Company’s Class A common stock for the three and nine

months ended September 30, 2024, respectively, were excluded from the calculation of diluted net income (loss)

attributable to common stockholders because their effect would have been anti-dilutive.

 

F-22


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

Note 18 – Supplemental Cash Flow Information

The following table sets forth supplemental disclosure of cash flow information (in millions):

 

     Nine months ended
September 30,
 
     2024      2023  

Accrued purchases of property, plant and equipment

   $ 1,863      $ 1,582  

Conversion of equity method investment to property, plant and equipment

     319        —   

Cash paid for interest, net of amounts capitalized

     292        277  

Accrued dividends and distributions

     135        —   

Right-of-use assets in exchange for new finance lease liabilities

     178        10  

Right-of-use assets in exchange for new operating lease liabilities

     180        26  

Paid-in-kind distribution on redeemable stock of subsidiary

     107        96  

Paid-in-kind distribution on non-controlling interests

     —         28  

Paid-in-kind interest on debt

     —         35  

Asset retirement obligation additions and revisions

     56        77  

Cash paid for operating leases

     58        40  

Accrued financing and issuance costs

     40        —   

Cash paid for income taxes

     9        107  

Note 19 – Segment Information

The following tables present financial information by reportable segment and a reconciliation of the Company’s segment Income from operations to Income (loss) before income tax expense (benefit) on the Condensed Consolidated Statements of Operations for the periods indicated (in millions):

 

     Three months ended
September 30,
     Nine months ended
September 30,
 
     2024      2023      2024      2023  

Revenue

           

Calcasieu Pass Project

   $ 1,024      $ 1,054      $ 3,546      $ 6,265  

Corporate, other and eliminations

     (98      —         (98      —   
  

 

 

    

 

 

    

 

 

    

 

 

 

Total Revenue

   $ 926      $ 1,054      $ 3,448      $ 6,265  
  

 

 

    

 

 

    

 

 

    

 

 

 

 

F-23


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

     Three months ended
September 30,
     Nine months ended
September 30,
 
      2024        2023       2024      2023  

Income (loss) from operations

           

Calcasieu Pass Project

   $ 540      $ 534      $ 2,066      $ 4,625  

Plaquemines Project

     (57      (59      (163      (132

CP2 LNG Project

     (106      (120      (396      (233

Corporate, other and eliminations

     (188      (46      (338      (147
  

 

 

    

 

 

    

 

 

    

 

 

 

Total income from operations

     189        309        1,169        4,113  
  

 

 

    

 

 

    

 

 

    

 

 

 

Interest income

     53        44        187        103  

Interest expense, net

     (128      (154      (467      (448

Gain (loss) on derivatives

     (480      788        70        830  

Loss on financing transactions

     (6      (3      (14      (113
  

 

 

    

 

 

    

 

 

    

 

 

 

Income (loss) before income tax expense (benefit)

   $ (372    $ 984      $ 945      $ 4,485  
  

 

 

    

 

 

    

 

 

    

 

 

 

 

     Total assets  
     September 30,
2024
     December 31,
2023
 

Calcasieu Pass Project

   $ 7,407      $ 7,571  

Plaquemines Project

     20,701        12,734  

CP2 LNG Project

     2,979        1,359  

Corporate, other and eliminations

     8,336        6,799  
  

 

 

    

 

 

 

Total

   $ 39,423      $ 28,463  
  

 

 

    

 

 

 

 

F-24


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

Note 20 – Recent Accounting Pronouncements

The following table provides a description of recently issued accounting pronouncements that have not yet been adopted by the Company as of September 30, 2024. Accounting pronouncements not listed below were assessed and determined to not have a material impact to the Company’s condensed consolidated financial statements.

 

Standard

  

Description

  

Effect on our condensed
consolidated financial statements

ASU 2023-07, Segment Reporting (Topic 280)   

In November 2023, the FASB issued ASU 2023-07, which improves reportable segment disclosure requirements. This requires disclosure about significant segment expenses regularly provided to the CODM, extending certain annual disclosures to interim periods, clarifying that single reportable segment entities must comply with ASC 280, permitting more than one measure of segment profit or loss to be reported under certain conditions, and disclosing the title and position of the CODM.

 

The standard is effective for fiscal years beginning after December 15, 2023, and interim periods within fiscal years beginning after December 15, 2024. Early adoption is permitted. The standard should be applied on a retrospective basis.

   The Company is currently evaluating the impact on our financial statement disclosures.
ASU 2023-09, Income Taxes (Topic 740)   

In December 2023, the FASB issued ASU 2023-09, which enhances tax-related disclosures by requiring public business entities to disclose a tabular reconciliation, using both percentages and amounts, broken into specific categories with certain reconciling items at or above 5% of the statutory (i.e., expected) tax, further broken out by nature and/or jurisdiction; for all other entities, qualitative disclosure of the nature and effect of significant reconciling items by specific categories and individual jurisdictions; and income taxes paid (net of refunds received), broken out between federal (national), state/local and foreign, and amounts paid to an individual jurisdiction when 5% or more of the total income taxes paid.

 

The standard is effective for fiscal years beginning after December 15, 2024, and interim periods within fiscal years beginning after December 15, 2025. Early adoption is permitted. The standard should be applied on a prospective basis, and retrospective application is permitted.

   The Company is currently evaluating the impact on our financial statement disclosures.

 

F-25


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

(unaudited)

 

Note 21 – Subsequent Events

Management has evaluated subsequent events after the balance sheet date and through the date of issuance of the condensed consolidated financial statements, November 1, 2024, for appropriate accounting and disclosure. The Company has determined that there were no such events that warrant disclosure or recognition in the condensed consolidated financial statements except for the following:

In October 2024, the Company received a final award related to arbitration with one of its construction contractors regarding certain disputes under a construction contract. See Note 13 - Contingencies for further discussion.

 

F-26


Table of Contents

Report of Independent Registered Public Accounting Firm

To the Shareholders and Board of Directors of Venture Global, Inc.

Opinion on the Financial Statements

We have audited the accompanying consolidated balance sheets of Venture Global, Inc. (the Company) as of December 31, 2023 and 2022, the related consolidated statements of operations, comprehensive income (loss), changes in equity (deficit) and cash flows for each of the three years in the period ended December 31, 2023, and the related notes (collectively referred to as the “consolidated financial statements”). In our opinion, the consolidated financial statements present fairly, in all material respects, the financial position of the Company at December 31, 2023 and 2022, and the results of its operations and its cash flows for each of the three years in the period ended December 31, 2023, in conformity with U.S. generally accepted accounting principles.

Basis for Opinion

These financial statements are the responsibility of the Company’s management. Our responsibility is to express an opinion on the Company’s financial statements based on our audits. We are a public accounting firm registered with the Public Company Accounting Oversight Board (United States) (PCAOB) and are required to be independent with respect to the Company in accordance with the U.S. federal securities laws and the applicable rules and regulations of the Securities and Exchange Commission and the PCAOB.

We conducted our audits in accordance with the standards of the PCAOB. Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are free of material misstatement, whether due to error or fraud. The Company is not required to have, nor were we engaged to perform, an audit of its internal control over financial reporting. As part of our audits, we are required to obtain an understanding of internal control over financial reporting but not for the purpose of expressing an opinion on the effectiveness of the Company’s internal control over financial reporting. Accordingly, we express no such opinion.

Our audits included performing procedures to assess the risks of material misstatement of the financial statements, whether due to error or fraud, and performing procedures that respond to those risks. Such procedures included examining, on a test basis, evidence regarding the amounts and disclosures in the financial statements. Our audits also included evaluating the accounting principles used and significant estimates made by management, as well as evaluating the overall presentation of the financial statements. We believe that our audits provide a reasonable basis for our opinion.

Critical Audit Matter

The critical audit matter communicated below is a matter arising from the current period audit of the financial statements that was communicated or required to be communicated to those charged with governance and that: (1) relates to accounts or disclosures that are material to the financial statements and (2) involved our especially challenging, subjective, or complex judgments. The communication of the critical audit matter does not alter in any way our opinion on the consolidated financial statements, taken as a whole, and we are not, by communicating the critical audit matter below, providing a separate opinion on the critical audit matter or on the accounts or disclosures to which it relates.

 

F-27


Table of Contents

Accounting for Costs of Construction and Development

 

Description of the Matter    As described in Note 2 to the consolidated financial statements, the Company’s liquefied natural gas (“LNG”) projects are constructed pursuant to the terms of construction and equipment supplier arrangements. The treatment of the costs incurred under these arrangements is dependent on the project’s stage of development. As described in Note 2, generally, the costs incurred to develop the Company’s LNG projects are recognized as development expenses until management concludes that construction and completion of the project is probable; afterwards such costs are capitalized. As of December 31, 2023, the Company had capitalized costs of approximately $19.4 billion into Property, plant, and equipment, net and had recognized expenses for development of LNG projects of approximately $0.5 billion during the year then ended. The construction and equipment supplier arrangements also contain various terms including retainage, performance bonuses, and liquidated damages, that impact the amount and timing of the recognition of the related costs.
   Auditing the Company’s costs of construction and development involved an increased extent of audit effort to evaluate treatment as being capitalized or expensed and whether they were recorded consistent with the terms of the construction and equipment supplier agreements in accordance with accounting principles generally accepted in the United States of America (US GAAP).
How We Addressed the Matter in Our Audit    Our audit procedures included, among others, inspection of a sample of the construction and equipment supplier arrangements, amendments, and any change orders to understand the key terms and conditions. We confirmed the terms and conditions directly with a sample of the Company’s major construction and equipment suppliers. For a sample of costs recognized during the year, we inspected invoices, construction reports and other supporting documents to test that they were recognized at the correct amount, in the correct period, and were recognized as capital or expense in accordance with the Company’s probability assessment of the related LNG project. Further, we obtained and tested the Company’s assessment of the probability of each LNG project being constructed and completed; including testing whether appropriate regulatory approvals, permits, LNG off-take contracts and construction and supplier contracts had been obtained.

 

/s/ Ernst & Young LLP
We have served as the Company’s auditor since 2020.
Tysons, VA
February 22, 2024

 

F-28


Table of Contents

VENTURE GLOBAL, INC.

CONSOLIDATED BALANCE SHEETS

($ in millions, except par values and share amounts)

 

     December 31,  
     2023     2022  

ASSETS

    

Current assets

    

Cash and cash equivalents

   $ 4,823     $ 618  

Restricted cash

     520       391  

Accounts receivable

     265       190  

Inventory

     44       26  

Derivative assets

     164       146  

Prepaid expenses and other current assets

     143       41  
  

 

 

   

 

 

 

Total current assets

     5,959       1,412  
  

 

 

   

 

 

 

Property, plant and equipment, net

     19,439       10,606  

Right-of-use assets

     381       327  

Noncurrent restricted cash

     529       1,403  

Deferred financing costs

     464       304  

Noncurrent derivative assets

     899       973  

Equity method investments

     539       —   

Other noncurrent assets

     253       72  
  

 

 

   

 

 

 

TOTAL ASSETS

   $ 28,463     $ 15,097  
  

 

 

   

 

 

 

LIABILITIES AND EQUITY

    

Current liabilities

    

Accounts payable

   $ 436     $ 252  

Accrued and other liabilities

     1,701       1,344  

Current portion of long-term debt

     178       150  
  

 

 

   

 

 

 

Total current liabilities

     2,315       1,746  
  

 

 

   

 

 

 

Long-term debt, net including $4,944 and $0, respectively, of debt related to variable interest entities

     20,607       10,458  

Noncurrent operating lease liabilities

     383       337  

Deferred tax liabilities, net

     1,149       474  

Other noncurrent liabilities

     539       318  
  

 

 

   

 

 

 

Total liabilities

     24,993       13,333  
  

 

 

   

 

 

 

Commitments and contingencies (Note 15)

    

Redeemable stock of subsidiary

     1,385       1,255  

Equity

    

Venture Global, Inc. stockholders’ and members’ equity (deficit)

    

Class A common stock, par value $0.01 per share (519,772 shares issued and outstanding at December 31, 2023 and 0 shares issued and outstanding at December 31, 2022)

     —        —   

Members’ deficit

     —        (690

Additional paid in capital

     542       —   

Retained earnings

     1,228       688  

Accumulated other comprehensive loss

     (260     (184
  

 

 

   

 

 

 

Total Venture Global, Inc. stockholders’ and members’ equity (deficit)

     1,510       (186

Non-controlling interests

     575       695  
  

 

 

   

 

 

 

Total equity

     2,085       509  
  

 

 

   

 

 

 

TOTAL LIABILITIES AND EQUITY

   $ 28,463     $ 15,097  
  

 

 

   

 

 

 

The accompanying notes are an integral part of these consolidated financial statements.

 

F-29


Table of Contents

VENTURE GLOBAL, INC.

CONSOLIDATED STATEMENTS OF OPERATIONS

($ in millions, except share and per share amounts)

 

     Years ended December 31,  
     2023     2022     2021  

REVENUE

   $ 7,897     $ 6,448     $ —   
  

 

 

   

 

 

   

 

 

 

OPERATING EXPENSE

      

Cost of sales (exclusive of depreciation and amortization shown separately below)

     1,684       2,093       —   

Operating and maintenance expense

     391       140       58  

General and administrative expense

     224       191       89  

Development expense

     490       311       188  

Depreciation and amortization

     277       158       6  

Insurance recoveries, net

     (19     —        (4
  

 

 

   

 

 

   

 

 

 

Total operating expense

     3,047       2,893       337  
  

 

 

   

 

 

   

 

 

 

INCOME (LOSS) FROM OPERATIONS

     4,850       3,555       (337

OTHER INCOME (EXPENSE)

      

Interest income

     172       18       —   

Interest expense, net

     (641     (592     (52

Gain on derivatives, net

     174       1,212       38  

Gain (loss) on embedded derivative

     —        (14     12  

Loss on financing transactions

     (123     (635     (97
  

 

 

   

 

 

   

 

 

 

Total other expense

     (418     (11     (99
  

 

 

   

 

 

   

 

 

 

INCOME (LOSS) BEFORE INCOME TAX EXPENSE

     4,432       3,544       (436

Income tax expense

     816       447       —   
  

 

 

   

 

 

   

 

 

 

NET INCOME (LOSS)

   $ 3,616     $ 3,097     $ (436
  

 

 

   

 

 

   

 

 

 

Less: Net income attributable to redeemable stock of subsidiary

     130       118       107  

Less: Net income (loss) attributable to non-controlling interests

     805       1,121       (187
  

 

 

   

 

 

   

 

 

 

NET INCOME (LOSS) ATTRIBUTABLE TO COMMON STOCKHOLDERS AND MEMBERS

   $ 2,681     $ 1,858     $ (356
  

 

 

   

 

 

   

 

 

 

BASIC EARNINGS (LOSS) PER SHARE

      

Net income attributable to common stockholders per share—basic

   $ 5,855     $ 4,266     $ (817

Weighted average number of shares of common stock outstanding—basic (a)

     457,896       435,500       435,500  

DILUTED EARNINGS (LOSS) PER SHARE

      

Net income attributable to common stockholders per share—diluted

   $ 5,656     $ 4,266     $ (817

Weighted average number of shares of common stock outstanding—diluted (a)

     474,033       435,500       435,500  

 

(a)

See Note 20 – Earnings (Loss) per Share for further discussion regarding the weighted average number of shares of common stock outstanding.

The accompanying notes are an integral part of these consolidated financial statements.

 

F-30


Table of Contents

VENTURE GLOBAL, INC.

CONSOLIDATED STATEMENTS OF COMPREHENSIVE INCOME (LOSS)

($ in millions)

 

     Years ended December 31,  
     2023     2022      2021  

NET INCOME (LOSS)

   $ 3,616     $ 3,097      $ (436

Other comprehensive income (loss)

       

Cash flow hedges, net

       

Change in fair value, net of income tax (expense) benefit of $2, $(25), and $0, respectively

     (8     88        70  

Reclassification to earnings, net of income tax expense of $1, $3, and $0, respectively

     4       7        —   
  

 

 

   

 

 

    

 

 

 

Total change in cash flow hedges, net

     (4     95        70  
  

 

 

   

 

 

    

 

 

 

COMPREHENSIVE INCOME (LOSS)

   $ 3,612     $ 3,192      $ (366
  

 

 

   

 

 

    

 

 

 

Less: Comprehensive income attributable to redeemable stock of subsidiary

     130       118        107  

Less: Comprehensive income (loss) attributable to non-controlling interests

     803       1,156        (159
  

 

 

   

 

 

    

 

 

 

COMPREHENSIVE INCOME (LOSS) ATTRIBUTABLE TO COMMON STOCKHOLDERS AND MEMBERS

   $ 2,679     $ 1,918      $ (314
  

 

 

   

 

 

    

 

 

 

The accompanying notes are an integral part of these consolidated financial statements.

 

F-31


Table of Contents

VENTURE GLOBAL, INC.

CONSOLIDATED STATEMENTS OF CHANGES IN EQUITY (DEFICIT)

($ in millions, except share amounts)

 

    Stockholders’ and members’ equity (deficit)        
    Common stock     Members’
capital
    Additional
paid in
capital
    Retained
earnings
(deficit)
    Accumulated
other
comprehensive
loss
    Total
stockholders’
and
members’
equity
(deficit)
    Non-controlling
interests
 
    Class A  
    Shares     Par value  

BALANCE AT DECEMBER 31, 2020

    —      $ —      $ 446     $ —      $ (814   $ (246   $ (614   $ 89  

Net loss

    —        —        —        —        (356     —        (356     (187

Stock-based compensation

    —        —        —        —        —        —        —        20  

Distributions

    —        —        (7     —        —        —        (7     —   

Other comprehensive income

    —        —        —        —        —        42       42       28  

Purchase of non-controlling interests

    —        —        (222     —        —        (18     (240     56  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

BALANCE AT DECEMBER 31, 2021

    —        —        217       —        (1,170     (222     (1,175     6  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income

    —        —        —        —        1,858       —        1,858       1,121  

Stock-based compensation

    —        —        —        —        —        —        —        26  

Distributions

    —        —        (6     —        —        —        (6     —   

Other comprehensive income

    —        —        —        —        —        60       60       35  

Purchase of non-controlling interests

    —        —        (901     —        —        (22     (923     (493
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

BALANCE AT DECEMBER 31, 2022

    —        —        (690     —        688       (184     (186     695  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Net income

    —        —        —        —        2,681       —        2,681       805  

Stock-based compensation

    —        —        —        (141     —        —        (141     17  

Distributions

    —        —        —        —        (149     —        (149     (29

Other comprehensive loss

    —        —        —        —        —        (2     (2     (2

Merger of Legacy VG Partners with Venture Global (the 2023 Merger)

    435,500       —        1,781       171       (1,992     —        (40     —   

Purchase of non-controlling interests

    84,272       —        (1,091     512       —        (74     (653     (911
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

BALANCE AT DECEMBER 31, 2023

    519,772     $  —      $ —      $ 542     $ 1,228     $ (260   $ 1,510     $ 575  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

The accompanying notes are an integral part of these consolidated financial statements.

 

F-32


Table of Contents

VENTURE GLOBAL, INC.

CONSOLIDATED STATEMENTS OF CASH FLOWS

($ in millions)

 

     Years ended December 31,  
     2023     2022     2021  

OPERATING ACTIVITIES

      

Net income (loss)

   $ 3,616     $ 3,097     $ (436

Adjustments to reconcile net income (loss) to net cash from operating activities:

      

Gain on derivatives, net

     (174     (1,198     (50

Net cash from (used for) settlement of derivatives

     203       (5     (231

Loss on financing transactions

     122       630       95  

Deferred taxes

     674       446       —   

Non-cash interest expense

     85       218       15  

Depreciation and amortization

     277       158       6  

Stock-based compensation

     28       26       20  

Reduction of right-of-use assets

     23       15       7  

Changes in operating assets and liabilities:

      

Accounts receivable

     (75     (190     —   

Inventory

     (18     (26     —   

Prepaid expenses and other current assets

     (96     10       (22

Accounts payable and accrued liabilities

     (55     541       66  

Operating lease liabilities

     (29     (9     2  

Other, net

     (31     (11     25  
  

 

 

   

 

 

   

 

 

 

Net cash from (used by) operating activities

     4,550       3,702       (503
  

 

 

   

 

 

   

 

 

 

INVESTING ACTIVITIES

      

Purchases of property, plant and equipment

     (8,091     (4,618     (2,009

Deposits for construction services and equipment

     (64     (96     (70

Proceeds from test LNG sales

     —        1,797       —   

Purchase of equity method investments

     (539     —        —   

Maturities of investments—certificates of deposit

     72       50       12  

Purchases of investments—certificates of deposit

     (88     (30     (1

Other investing activities

     (15     (3     (10
  

 

 

   

 

 

   

 

 

 

Net cash used by investing activities

     (8,725     (2,900     (2,078
  

 

 

   

 

 

   

 

 

 

FINANCING ACTIVITIES

      

Proceeds from issuance of debt

     12,278       5,974       5,396  

Proceeds from project credit facilities

     3,875       1,695       2,375  

Repayment of debt

     (5,918     (5,043     (3,272

Purchase of non-controlling interests

     (1,564     (1,417     (185

Payments of financing and issuance costs

     (591     (886     (134

Distributions

     (164     (6     (7

Financed purchases of property, plant and equipment

     (108     (67     (267

Other financing activities

     (173     (15     (283
  

 

 

   

 

 

   

 

 

 

Net cash from financing activities

     7,635       235       3,623  
  

 

 

   

 

 

   

 

 

 

Net increase in cash, cash equivalents and restricted cash

     3,460       1,037       1,042  

Cash, cash equivalents and restricted cash at beginning of period

     2,412       1,375       333  
  

 

 

   

 

 

   

 

 

 

CASH, CASH EQUIVALENTS AND RESTRICTED CASH AT END OF PERIOD

   $ 5,872     $ 2,412     $ 1,375  
  

 

 

   

 

 

   

 

 

 

The accompanying notes are an integral part of these consolidated financial statements.

 

F-33


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

Note 1 – The Company

Venture Global, Inc. (“Venture Global”) is a Delaware corporation formed by the managing members of Venture Global Partners II, LLC (“VG Partners”) on September 19, 2023, under the name of Venture Global Holdings, Inc. In January 2024, the Company changed its name from Venture Global Holdings, Inc. to Venture Global, Inc. As used in these consolidated financial statements, unless the context otherwise requires, references to the “Company,” “we,” “us,” and “our” refer to Venture Global (or Legacy VG Partners, as applicable, and as defined and explained below) and its consolidated subsidiaries.

In September 2023, Venture Global was party to certain reorganization transactions (the “Reorganization Transactions”) whereby Venture Global Partners, LLC (“Legacy VG Partners”), a then wholly-owned subsidiary of VG Partners and controlling shareholder of Venture Global LNG, Inc. (“VGLNG”), merged with and into Venture Global (the “2023 Merger”), with VG Partners receiving 435,500 shares of Venture Global’s Class A common stock in exchange for 100% of its equity interests in Legacy VG Partners. In connection with the Reorganization Transactions, the non-controlling VGLNG shareholders, holding 84,272 shares of VGLNG’s issued and outstanding Series C common stock, received 84,272 shares of Class A common stock of Venture Global, in a one-for-one exchange for their shares of VGLNG (the “NCI Acquisition”). All shares of Series A, Series B and Series C common stock of VGLNG were retired upon completion of the Reorganization Transactions in September 2023. No cash was exchanged as part of the Reorganization Transactions and Venture Global incurred $40 million of third- party transaction costs in connection with its formation and the issuance of its shares of Class A common stock.

The 2023 Merger was accounted for as a transaction between entities under common control which represented a change in reporting entity. The NCI Acquisition was accounted for as a change in Venture Global’s ownership interest in a subsidiary within equity on a prospective basis. Prior to the 2023 Merger, Venture Global, as a standalone entity, had no operations, and no assets or liabilities. The financial results and other information included in these consolidated financial statements for periods prior to the Reorganization Transactions were applied on a retrospective basis and are reflective of Legacy VG Partners, except for earnings per share. Historical earnings per share was calculated based on the one-for-one exchange ratio of the 435,500 shares of Venture Global’s Class A common stock issued to VG Partners in exchange for 100% of the Legacy VG Partners equity interests in connection with the 2023 Merger. The shares issued as part of the NCI Acquisition are included in earnings per share prospectively from the date of the Reorganization Transactions. See Note 20 – Earnings (Loss) per Share for further discussion.

The Company is headquartered in Arlington, Virginia, and has offices in Houston, Texas; London, England; Tokyo, Japan; and Singapore.

The Company sells liquefied natural gas (“LNG”) and is engaged in the development, construction, and operation of natural gas liquefaction and export facilities in North America (“LNG projects”). Each LNG project includes a liquefaction facility and export terminal and one or more associated pipelines that interconnect with several interstate and intrastate pipelines for delivery of natural gas into the associated liquefaction facility and export terminal. Below is a summary of our current LNG projects.

 

Project name

  

Terminal entity

  

Pipeline(s) entity

Calcasieu Pass Project   

Venture Global Calcasieu Pass, LLC

(“Calcasieu Pass”)

  

TransCameron Pipeline, LLC

(“TransCameron”)

Plaquemines Project   

Venture Global Plaquemines LNG, LLC

(“Plaquemines”)

  

Venture Global Gator Express, LLC

(“Gator Express”)

CP2 LNG Project   

Venture Global CP2 LNG, LLC

(“CP2”)

  

Venture Global CP Express, LLC

(“CP Express”)

Delta LNG Project   

Venture Global Delta LNG, LLC

(“Delta”)

  

Venture Global Delta Express, LLC

(“Delta Express”)

 

F-34


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Commencement of the construction of each of our LNG projects is subject to the receipt of the appropriate regulatory approvals and permits, entering into LNG sales contracts with respect to an adequate amount of anticipated nameplate capacity, securing equipment and construction contracts and securing adequate financing arrangements.

The Calcasieu Pass Project has contracted to sell 10.0 million metric tonnes per annum (“MTPA”) of LNG under six 20-year, one 5-year, and one 3-year sales and purchase agreements (“SPAs”) on a post-commercial operation date (“COD”) term basis. The Calcasieu Pass Project is located in Cameron Parish, Louisiana on leased land with access to deep-water frontage on the Calcasieu Ship Channel near the Gulf of Mexico. In the first quarter of 2022, the Company began producing and selling LNG from the Calcasieu Pass Project while undergoing commissioning. The Calcasieu Pass Project is still in its commissioning phase and various corrective, remedial, warranty and other work is being performed before the facility can be declared complete and commercially operable for the purposes of its post-COD term SPAs.

The Plaquemines Project is being built in two phases. The Plaquemines Project has contracted to sell 13.3 MTPA and 6.7 MTPA of LNG from the first and second phase of the Plaquemines Project, respectively, under 14 predominantly 20-year SPAs on a post-COD term basis. The Plaquemines Project is located in Plaquemines Parish, Louisiana on leased land with access to deep-water frontage on the Mississippi River near the Gulf of Mexico. The Plaquemines Project is under construction after securing the full project-level financing required to complete the first and second phases of the project.

The CP2 LNG Project is expected to be built in two phases. The CP2 LNG Project has contracted to sell 9.25 MTPA of LNG from the CP2 LNG Project under eight 20-year SPAs on a post-COD term basis. The CP2 LNG Project is located in Cameron Parish, Louisiana near the Calcasieu Pass Project on the Calcasieu Ship Channel near the Gulf of Mexico. The CP2 LNG Project is in the development and permitting phase with major engineering and procurement work underway, and has yet to secure the full project-level financing required to complete the first phase of the project. While the Federal Energy Regulatory Commission (“FERC”) has issued the final Environmental Impact Statement (“EIS”) for the CP2 LNG Project, the final FERC order on the CP2 LNG Project application and the approval from the Department of Energy (“DOE”) to export LNG produced by the CP2 LNG Project to non-free trade agreement (“non-FTA”) nations are still pending.

The Delta LNG Project is expected to be built in two phases. The Delta LNG Project is located in Plaquemines Parish, Louisiana with access to deep-water frontage on the Mississippi River near the Gulf of Mexico. The Delta LNG Project is in the early permitting and development phase and has yet to secure the full project-level financing and regulatory permits and approvals required to complete the first phase of the project. The Delta LNG Project received acceptance from FERC of its pre-filing submission, starting the environmental review process.

The Company is also engaged in the acquisition, and eventual operation and management, of LNG tankers to support its LNG projects. The Company has five LNG tankers under construction which are expected to be delivered on a rolling basis between 2025 through 2026. The Company has contracts to acquire four additional LNG tankers through the purchase of equity interests in certain third party entities, which are expected to be delivered between 2024 through 2025. See Note 8 – Equity Method Investments for further discussion.

Note 2 – Summary of Significant Accounting Policies

Basis of presentation and consolidation

The accompanying consolidated financial statements have been prepared in accordance with generally accepted accounting principles in the United States of America (“GAAP”). The consolidated financial statements include the accounts of Venture Global and its controlled subsidiaries. All intercompany transactions and balances have

 

F-35


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

been eliminated in consolidation. The financial results and other information included in these consolidated financial statements for periods prior to the Reorganization Transactions are reflective of Legacy VG Partners, except for earnings per share.

Variable interest entities

Entities in which the Company has variable interests (“VIEs”) have been consolidated where the Company is the primary beneficiary. Plaquemines and Gator Express were determined to be wholly-owned VIEs due to the financing structure of the second phase of the Plaquemines Project. The Company is the primary beneficiary of Plaquemines and Gator Express since it has the power to make significant decisions. The assets held by Plaquemines and Gator Express are restricted to use on those entities. See Note 3 – Restricted Cash and Note 6 – Property, Plant and Equipment for further discussion.

Going concern

The consolidated financial statements have been prepared under the assumption the Company will continue as a going concern, which contemplates the realization of assets and satisfaction of liabilities in the normal course of business. Management expects to have sufficient financial resources to operate beyond the next twelve months following the date these consolidated financial statements are issued.

A summary of the significant accounting policies applied in the preparation of the accompanying consolidated financial statements follows.

Use of estimates

The preparation of consolidated financial statements in conformity with GAAP requires management to make estimates and assumptions that affect the reported amounts in the consolidated financial statements and in the accompanying notes. While management believes that the estimates and assumptions used in the preparation of the consolidated financial statements are appropriate, actual results could differ from those estimates.

Concentration of credit risk

Financial instruments that potentially subject the Company to a concentration of credit risk consist primarily of derivative instruments and accounts receivable related to our LNG sales contracts. Additionally, we maintain cash balances at financial institutions, which may at times be in excess of federally insured levels. We have not incurred credit losses related to these cash balances to date.

The use of derivative instruments exposes us to counterparty credit risk, or the risk that a counterparty will be unable to meet its commitments. Exposure to credit risk is limited to the amounts, if any, by which the counterparty’s obligations under the derivative contracts exceed the obligations of the Company to the counterparty. The Company mitigates this exposure by minimizing counterparty concentrations, entering into master netting arrangements and generally entering into derivative contracts with large multinational financial institutions. The Company does not believe there is a material risk of counterparty non-performance. 

The Company is dependent on our customers’ creditworthiness and their willingness to perform under their respective agreements. See Note 23 – Segment Information for additional details about our customer concentration.

Fair value measurements

Fair value is the price that would be received to sell an asset or paid to transfer a liability in an orderly transaction between market participants. The carrying values of the Company’s Cash and cash equivalents, Restricted cash,

 

F-36


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Accounts receivable, Accounts payable and Accrued and other liabilities approximate fair value due to their short-term maturities. The Company applies the fair value measurement guidance to financial assets and liabilities included in the Cash and cash equivalents, Derivative assets, Noncurrent derivative assets, Accrued and other liabilities and Other noncurrent liabilities line items on the Consolidated Balance Sheets. Hierarchy Levels 1, 2 and 3 are terms for the priority of inputs to valuation approaches used to measure fair value. In determining fair value, the Company prioritizes the use of observable market data when available. Assets and liabilities are categorized within the fair value hierarchy based upon the lowest level of input that is significant to the fair value measurement:

 

   

Level 1: Quoted prices in active markets for identical assets or liabilities

 

   

Level 2: Inputs other than quoted prices in active markets that are directly or indirectly observable for the asset or liability

 

   

Level 3: Inputs that are not observable in the market

Transfers between Level 2 and Level 3 result from changes in the significance of unobservable inputs used to determine fair value and are recognized as of the beginning of the reporting period in which they occur. For further discussion, see Note 13 – Fair Value Measurements.

Cash and cash equivalents

The Company considers money market funds, commercial paper and all highly liquid investments with original maturities of three months or less at the time of purchase to be cash equivalents.

Restricted cash

The Company holds certain financial instruments that are restricted as to withdrawal and use under the terms of certain contractual arrangements. These amounts are presented separately from Cash and cash equivalents on the Consolidated Balance Sheets. For further discussion, see Note 3 – Restricted Cash.

Revenue recognition

The majority of the Company’s nameplate liquefaction capacity produced after an LNG project reaches commercial operations will be sold under long-term 20-year SPAs (“post-COD term SPAs”). In this context, “commercial operations” represents the production period commencing after the occurrence of the commercial operations date (“COD”) of the relevant project or phase thereof as specifically defined in the relevant SPAs. Under each post-COD term SPA, COD does not occur unless and until: (i) all of the facilities comprising the relevant project or phase thereof, have been completed and commissioned, including any ramp up period, (ii) the project or phase thereof is capable of delivering LNG in sufficient quantities and necessary quality to perform all of its obligations under the post-COD term SPA, and (iii) the applicable project company has notified the customer.

LNG produced prior to the relevant project or phase thereof reaching COD is sold under short-term sales agreements (“Early Cargo Sales Agreements”), at prevailing market prices when executed. COD has not yet occurred for any of our LNG projects or phases thereof, and accordingly, LNG revenue recognized during the years ended December 31, 2023 and 2022, was earned under Early Cargo Sales Agreements.

The Company recognizes revenue when we transfer control of promised goods or services to our customers in an amount that reflects the consideration we expect to be entitled to receive in exchange for those goods or services. Revenue from the sale of LNG is recognized at the point in time when the LNG is delivered to the customer at

 

F-37


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

the agreed upon LNG terminal which is the point when legal title, physical possession and the risks and rewards of ownership transfer to the customer. Each individual molecule of LNG is viewed as a separate performance obligation. The stated contract price, including both fixed and variable components, is representative of the stand-alone selling price for LNG at the time the contract was negotiated. Payment terms are within 30 days after the LNG is delivered.

Proceeds from the sale of test LNG generated during the early commissioning of an LNG project (“test LNG sales”) are determined based on estimates of LNG production generated from commissioning activities and recognized as a reduction to the cost basis of construction in progress until assets are placed in service in accordance with the accounting guidance.

Accounts receivable

Accounts receivable are reported net of any current expected credit losses. Current expected credit losses consider the risk of loss based on counterparty credit worthiness, past events, current conditions and reasonable and supportable forecasts. There were no allowances for credit losses as of December 31, 2023 or 2022.

Inventory

Inventory consists of LNG inventory, spare parts and materials, and is recognized at the lower of weighted average cost and net realizable value. LNG inventory includes all costs incurred directly for the production of LNG. LNG inventory is recognized as Cost of sales, or as part of the cost basis of construction in progress if associated with test LNG sales, when transferred to the customer. Spare parts and materials are charged to Operating and maintenance expense as they are consumed.

Property, plant and equipment

Property, plant and equipment are recognized at cost, less accumulated depreciation and amortization. Certain assets undergo a commissioning process during which LNG is produced and sold as test LNG. Prior to being placed in service in accordance with the accounting guidance, net margin from test LNG sales, including sale proceeds and costs of production, are treated as a reduction of construction in progress. Depreciation is calculated using the straight-line depreciation method over the estimated useful life of the asset. The LNG terminal assets are depreciated on a straight-line basis over the shorter of their estimated useful life or the lease term of the land to which they are affixed. Leasehold improvements are depreciated on a straight-line basis over the shorter of the lease term or estimated useful life of the asset. Management tests property, plant and equipment for impairment whenever events or changes in circumstances indicate that the carrying amount of the assets might not be recoverable.

Construction in progress

Construction in progress represents the accumulation of project development costs and construction costs primarily related to the construction of the Company’s LNG projects. The Company capitalizes project development costs once construction of the relevant project is considered probable. Interest and other related costs incurred on debt obtained for construction of property, plant and equipment are capitalized over the shorter of the construction period or related debt term. Costs incurred for the purchase of major equipment components of the LNG projects are recognized as construction in progress upon the Company receiving or taking ownership of the equipment. No depreciation expense is recognized on construction in progress until the relevant assets are completed and placed in service in accordance with the accounting guidance.

Advance equipment and construction payments

Advance equipment and construction payments represent amounts paid to suppliers for certain major equipment components of the LNG projects that have yet to be delivered, advances toward the purchase of an LNG tanker

 

F-38


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

where title of the tanker does not transfer to the Company until the date of delivery, or amounts paid to contractors for services not yet performed. Pursuant to the terms of certain of our agreements, the Company is required to make payments in accordance with defined milestone payment schedules as related progress milestones are completed by the respective supplier or contractor. The construction and equipment supplier agreements also contain various terms including retainage, performance bonuses, and liquidated damages that impact the amount and timing of the recognition of the related costs. Prior to the Company receiving or taking ownership of the asset, payments are capitalized to advance equipment and construction payments at the time consideration is paid or becomes payable. The amounts are transferred to construction in progress once services are performed or the related asset is received or ownership is taken by the Company.

Project development costs

Generally, the costs incurred to develop the Company’s LNG projects or to acquire LNG tankers are treated as development expenses until management concludes that construction and completion of the relevant project or LNG tanker is probable. These costs primarily include professional fees associated with early engineering and design work, costs of securing necessary regulatory approvals and permits, and other preliminary investigation and development activities related to the projects. Management’s probability conclusion for LNG projects is primarily based on the achievement of, or ability to achieve, certain critical project development milestones, including, where appropriate, receipt of the appropriate regulatory approvals and permits, entering into LNG sales contracts with respect to an adequate amount of the anticipated nameplate capacity, securing equipment and construction contracts and securing adequate financing arrangements.

Generally, costs that are capitalized during the preliminary stage of development include land acquisition costs, certain environmental credits, leasehold improvement costs necessary for preparing the facilities for their intended use, and direct costs of construction-related activities incurred with third parties. This includes costs that are directly identifiable for the early procurement of equipment that is probable of being acquired prior to a relevant project being deemed probable of construction or completion and that have an alternative use.

For further discussion of the Company’s property, plant and equipment, see Note 6 – Property, Plant and Equipment.

Leases

We determine if an arrangement is, or contains, a lease at inception of the arrangement. When an arrangement is, or contains, a lease, we classify the lease as either an operating lease or a finance lease. Operating and finance leases are recognized on the Consolidated Balance Sheets as lease liabilities, representing the obligation to make future lease payments, and right-of-use assets, representing the right to use the underlying assets for the lease term. Operating and finance lease liabilities and right-of-use assets are generally recognized based on the present value of lease payments over the lease term. In determining the present value of lease payments, we use the implicit interest rate in the lease, if readily determinable. In the absence of a readily determinable implicit interest rate, we discount our expected future lease payments using the lessee’s incremental borrowing rate. The incremental borrowing rate is an estimate of the interest rate that a lessee would have to pay to borrow on a collateralized basis over a similar term to that of the lease term. Lease and non-lease components of an arrangement are combined in calculating the right-of-use asset and lease liability. Options to renew a lease are included in the lease term and recognized as a part of the right-of-use asset and lease liability, only to the extent they are reasonably certain to be exercised. Adjustments to lease payments due to changes in a variable index are treated as variable lease costs and recognized in the period in which they are incurred.

Operating lease expense is recognized on a straight-line basis over the lease term. Finance lease expense is recognized as the amortization of the right-of-use assets on a straight-line basis and the interest on lease liabilities using the

 

F-39


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

effective interest method over the lease term. Leases with an initial term of 12 months or less are not recognized on the Consolidated Balance Sheets and are expensed on a straight-line basis. For further discussion, see Note 7 – Leases.

Deferred financing costs

Deferred financing costs represent debt issuance costs incurred in connection with working capital facilities and term loans which have not yet been fully drawn. Deferred financing costs are amortized on a straight-line basis to interest expense over the availability period of the working capital facility or undrawn term loans. Once a term loan is fully drawn, its associated unamortized deferred financing costs are reclassified to a contra-liability in Long-term debt, net on the Consolidated Balance Sheets and are amortized to interest expense using the effective interest method over the remaining term of the debt.

Equity method investments

Investments in non-controlled entities in which the Company has the ability to exercise significant influence over operating and financial policies are accounted for using the equity method of accounting. In applying the equity method of accounting, investments are initially recognized at cost, and subsequently adjusted for our proportionate share of earnings, losses and distributions. The Company utilizes the cumulative earnings approach to determine whether distributions received from equity method investees are returns on investment or returns of investment. These investments are recognized as Equity method investments on our Consolidated Balance Sheets. For further discussion, see Note 8 – Equity Method Investments.

Rights-of-way

The Company obtains perpetual rights to construct, operate and maintain its pipelines on land owned or bodies of water controlled by third parties. The costs to obtain these rights are capitalized as indefinite-lived intangible assets in Other noncurrent assets on the Consolidated Balance Sheets. No amortization is recognized on these assets, as the rights-of-way are perpetual in nature.

Derivative instruments

The Company reflects all contracts that meet the definition of a derivative, except those designated and qualifying as normal purchase and normal sale, as either assets or liabilities on the Consolidated Balance Sheets at fair value. Changes in the fair value of derivative instruments are recognized in earnings, unless we elect to apply hedge accounting and meet the specified criteria in ASC 815, Derivatives and Hedging. The Company designates derivative instruments based on all available facts and circumstances.

The Company enters into interest rate swap agreements to mitigate volatility arising from changes in interest rates. We do not utilize derivatives for trading or speculative purposes. Derivative instruments are recognized at fair value on the Consolidated Balance Sheets. Changes in fair value of derivative instruments designated as cash flow hedges are recognized in accumulated other comprehensive loss (“AOCL”) until the hedged transaction affects earnings, at which time the deferred gains and losses are reclassified to earnings. Cash flows associated with derivatives hedging capitalized interest and designated as cash flow hedges are classified as investing activities in the Consolidated Statements of Cash Flows unless the derivatives contain an other-than-insignificant financing element at inception, in which case the associated cash flows are classified as financing activities. Cash flows of the Company’s derivatives which are not designated as hedging relationships are classified as operating activities in the Consolidated Statements of Cash Flows. Derivative assets and liabilities are presented net on the Consolidated Balance Sheets when a legally enforceable master netting arrangement exists with the counterparty. For further discussion, see Note 12 – Derivatives.

We discontinue hedge accounting on a prospective basis if the derivative is no longer expected to be highly effective as a hedge, if the hedged transaction is no longer probable of occurring, or if we de-designate the

 

F-40


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

instrument as a cash flow hedge. Any gain or loss in AOCL at the time of de-designation is reclassified into earnings in the same period the hedged transaction affects earnings unless the underlying hedged transaction is probable of not occurring, in which case, any gain or loss in AOCL is reclassified into earnings immediately.

The Company evaluates all of its financial instruments to determine if such instruments are freestanding derivatives or if they contain features that qualify as embedded derivatives. If an instrument contains more than one embedded feature that warrants separate accounting, those embedded features are bundled together as a single, compound embedded derivative that is bifurcated and accounted for separately from the host contract. Embedded derivatives are presented in the same line item of the Consolidated Balance Sheets as their host contracts. Embedded derivatives are initially recognized at fair value and marked to market at each balance sheet date with changes in fair value recognized in Loss on embedded derivative on the Consolidated Statements of Operations. For further discussion see Note 13 – Fair Value Measurements.

Accounts payable and Accrued and other liabilities

The Company recognizes invoiced amounts from our operating and construction vendors as Accounts payable on the Consolidated Balance Sheets. Accrued and other liabilities on the Consolidated Balance Sheets primarily represent amounts owed to our vendors but not yet invoiced, accrued interest, and accrued compensation costs. For further discussion, see Note 9 – Accrued and Other Liabilities.

Asset retirement obligations

The Company recognizes a liability at fair value for an asset retirement obligation (“ARO”) when the legal obligation to retire the asset has been incurred (i.e., as the asset is being constructed) and a reasonable estimate of fair value can be made. The ARO liability is classified as Other noncurrent liabilities on the Consolidated Balance Sheets with a corresponding increase to the carrying amount of the related long-lived asset. AROs are periodically adjusted to reflect changes in the estimated present value of the obligation resulting from revisions to the estimated timing or amount of the expected future cash flows. Upon settlement of the obligation, the Company eliminates the liability and, based on the actual cost to retire, may incur a gain or loss. For further discussion, see Note 10 – Asset Retirement Obligations.

Redeemable stock of subsidiary

Redeemable stock of subsidiary on the Consolidated Balance Sheets represents third-party interests in the net assets of the Company’s subsidiary, Calcasieu Pass Funding, LLC (“CP Funding”), resulting from the issuance of the Redeemable Preferred Units, as defined and discussed in Note 17 – Redeemable Stock of Subsidiary. The third-party has the right to redeem its interests for cash upon the occurrence of events not solely within the Company’s control, therefore the redeemable stock of subsidiary is classified outside of permanent equity, as mezzanine equity, on the Consolidated Balance Sheets. The balance is carried at its current redemption value as adjusted by the contractually stated distribution amount that is recognized in each reporting period as Net income attributable to redeemable stock of subsidiary on the Consolidated Statements of Operations.

Non-controlling interests

Non-controlling interests on the Consolidated Balance Sheets represent the portion of net assets in consolidated entities that are not owned by the Company. Non-controlling interests are recognized as a separate component of equity on the Consolidated Balance Sheets and are adjusted by the amount of earnings or other comprehensive income (loss) attributable to the non-controlling interests, distributions associated with the Convertible Preferred Units (as defined and discussed in Note 18 – Non-Controlling Interests) and changes in ownership interest. A change in ownership of a subsidiary while the controlling financial interest is retained is accounted for as an

 

F-41


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

equity transaction between the controlling and non-controlling interests. Losses are attributed to the non-controlling interests even when the non-controlling interests’ basis has been reduced to zero.

Operating expenses

Cost of sales is comprised of the direct cost of producing LNG recognized as revenue. It includes the cost of purchasing and transporting natural gas used in the production of LNG, also known as feed gas, and excludes depreciation and amortization, shown separately on the consolidated statements of operations.

General and administrative expense consists primarily of costs not directly associated with the operations or development of the Company’s LNG projects or tankers, such as the Company’s corporate support functions including executive management, information technology, human resources, legal, and finance.

Development expense primarily includes costs incurred to develop a project prior to management’s conclusion that construction and completion of that project is probable as well as construction stage costs that are not capitalizable. These expenses consist primarily of engineering and design expenses and other early stage development costs.

Stock-based compensation

The Company accounts for stock-based compensation using the fair value method. The grant-date fair value attributable to stock options is calculated based on the Black-Scholes option-pricing model and is amortized on a straight-line basis to expense over the vesting period of the award. Forfeitures are recognized as they occur. For further discussion, see Note 19 – Stock-Based Compensation.

Income taxes

Prior to the Reorganization Transactions, the Company was treated as a partnership for income tax purposes. As a result, the entity incurred no U.S. federal or state tax liability, and the taxable income of the Company was reported on the tax returns of the managing members. However, certain of its subsidiaries were subject to federal, state, local and foreign corporate income taxes. With the closing of the Reorganization Transactions, the Company is treated as a corporation for income tax purposes. The change in the tax status of the Company did not have a material impact on its income taxes.

The Company accounts for income taxes under the asset and liability method, which requires the recognition of deferred income tax assets and liabilities for the expected future tax consequences of events that have been included in the financial statements. Under this method, the Company determines income tax assets and liabilities based on the differences between the financial statement and income tax basis for assets and liabilities using the enacted statutory tax rates in effect for the year in which the differences are expected to reverse. The effect of a change in tax rate on deferred income tax assets and liabilities is recognized in income in the period that includes the enactment date. The Company’s accounting policy for releasing the income tax effects from AOCL occurs on a portfolio basis.

A valuation allowance is provided for deferred income taxes if it is more-likely-than-not these items will either expire before the Company is able to realize their benefits or if future deductibility is uncertain. Additionally, the Company evaluates tax positions under a more-likely-than-not recognition threshold and measurement analysis before the positions are recognized for financial statement reporting. For further discussion, see Note 14 – Income Taxes.

 

F-42


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Earnings (loss) per share

Basic net earnings (loss) per share is computed by dividing Net income (loss) attributable to common stockholders by the weighted-average number of shares of common stock outstanding during the period. Diluted net income (loss) per share is computed by giving effect to all potentially dilutive securities, including stock options outstanding. For further discussion, see Note 20 – Earnings (Loss) per Share.

Note 3 – Restricted Cash

The following table summarizes the components of restricted cash (in millions):

 

     December 31,  
     2023      2022  

Current restricted cash

     

Calcasieu Pass Project cash reserves (a)

   $ 520      $ 391  
  

 

 

    

 

 

 

Total current restricted cash

   $ 520      $ 391  
  

 

 

    

 

 

 

Noncurrent restricted cash

     

Plaquemines Project construction (b)

   $ 310      $ 993  

Calcasieu Pass Project cash reserves (c)

     219        269  

VGLNG debt service reserves

     —         141  
  

 

 

    

 

 

 

Total noncurrent restricted cash

   $ 529      $ 1,403  
  

 

 

    

 

 

 

 

(a)

Associated with pre-commercial operations LNG sales and restricted to use at the Calcasieu Pass Project.

(b)

Restricted to the payment of construction and commissioning costs for the Plaquemines Project.

(c)

Primarily associated with debt service reserves and restricted cash for construction and commissioning costs for the Calcasieu Pass Project.

The following table provides a reconciliation of cash, cash equivalents and restricted cash reported within the Consolidated Balance Sheets to the Consolidated Statements of Cash Flows (in millions):

 

     December 31,  
     2023      2022  

Cash and cash equivalents

   $ 4,823      $ 618  

Current restricted cash

     520        391  

Noncurrent restricted cash

     529        1,403  
  

 

 

    

 

 

 

Cash, cash equivalents and restricted cash per the Consolidated Statements of Cash Flows

   $ 5,872      $ 2,412  
  

 

 

    

 

 

 

Note 4 – Revenue from Contracts with Customers

The following table summarizes the disaggregation of revenue earned from contracts with customers (in millions):

 

     Years ended December 31,  
     2023      2022      2021  

LNG revenue

   $ 7,875      $ 6,433      $ —   

Other revenue

     22        15        —   
  

 

 

    

 

 

    

 

 

 

Total revenue

   $ 7,897      $ 6,448      $  —   
  

 

 

    

 

 

    

 

 

 

 

F-43


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

LNG revenue recognized during the years ended December 31, 2023 and 2022, was earned under Early Cargo Sales Agreements at prevailing market prices when executed.

LNG revenue

We have entered into numerous contracts for the sale of LNG to third-party customers. Our customers generally purchase LNG for a price which includes a fixed fee per metric million British thermal unit (“MMBtu”) of LNG (a portion of which is subject to annual adjustment for inflation) plus a variable fee per MMBtu of LNG indexed to Henry Hub. The fixed fee component under our post-COD term SPAs is the amount payable to us regardless of a cancellation or suspension of LNG cargo deliveries by the customers. The variable fee component is the amount generally payable to us only upon delivery of LNG, plus all future adjustments to the fixed fee for inflation. Sales under our Early Cargo Sales Agreements and post-COD term SPAs also include variable consideration for contingent penalties or fees which may be due from the Company, and if so, could result in the significant reversal of revenue. Estimates for penalties or fees are recognized as a reduction to the transaction price until the future significant reversal of revenue is no longer probable of occurring or once the uncertainty is resolved.

Transaction price allocated to future performance obligations

Because many of our sales contracts have long-term durations, we are contractually entitled to significant future consideration which we have not yet recognized as revenue. The following table discloses the aggregate amount of the transaction price, including variable consideration, that is allocated to performance obligations that have not yet been satisfied, excluding all performance obligations that are part of contracts that have an expected duration of one year or less (dollar amounts in millions):

 

     December 31, 2023  
     Unsatisfied transaction price
(a)
     Weighted average timing of
recognition
 

LNG revenue

   $ 190,704        20 years  

 

(a)

The transaction price is based on the forecasted Henry Hub index as of December 31, 2023.

Significant judgments were made when estimating the transaction price allocated to future performance obligations. These include the best estimate of when our respective projects will reach COD and their post-COD sales contracts commence, which we currently expect to occur in late 2024 for our Calcasieu Pass Project and in 2026 and 2027 for the first and second phases of our Plaquemines Project, respectively, and the most likely amount of variable consideration to which we expect to be entitled upon the resolution of certain ongoing disputes with customers. These disputes are with various Calcasieu Pass post-COD term SPA customers who are asserting that the Calcasieu Pass Project is delayed in declaring COD under the respective SPAs. These disputes are subject to aggregate liability limitations of $1.4 billion under the SPAs. Certain of our customers are also disputing whether the liability limitations in our SPAs are applicable, and therefore are claiming damages in excess of the liability limitations. Our estimates of variable consideration exclude decreases to the transaction price for these contingent penalties based on our best estimate of the most likely outcome of these disputes. We expect this variability to be resolved in 2025 upon the conclusion of various arbitration proceedings.

 

F-44


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Note 5 – Inventory

The following table summarizes the components of inventory (in millions):

 

     December 31,  
     2023      2022  

LNG

   $ 5      $ 20  

Spare parts and materials

     39        6  
  

 

 

    

 

 

 

Total inventory

   $ 44      $ 26  
  

 

 

    

 

 

 

Note 6 – Property, Plant and Equipment

The following table presents the components of property, plant and equipment, net (in millions) and their estimated useful lives (in years):

 

            December 31,  
     Estimated useful life      2023     2022  

LNG terminal and interconnected pipeline facilities

     5–27      $ 6,873     $ 6,811  

Construction in progress

     N/A        9,000       2,488  

Advanced equipment and construction payments

     N/A        3,617       1,325  

Finance lease assets

     3–11        101       91  

Leasehold improvements

     1–30        214       35  

Land

     N/A        26       10  

Other

     3–7        60       10  
     

 

 

   

 

 

 

Total property, plant and equipment at cost

        19,891       10,770  

Accumulated depreciation and amortization

        (452     (164
     

 

 

   

 

 

 

Total property, plant and equipment, net (a)

      $ 19,439     $ 10,606  
     

 

 

   

 

 

 

 

(a)

Includes $10.6 billion of Property, plant and equipment restricted to use at Plaquemines and Gator Express, which are wholly-owned consolidated VIEs.

On March 1, 2022 and June 30, 2022, management determined the first and second phase of the Plaquemines Project, respectively, were probable of construction and completion.

The following table presents depreciation expense recognized on the Company’s Consolidated Statements of Operations (in millions):

 

     Years ended December 31,  
   2023      2022      2021  

Depreciation expense

   $ 273      $ 154      $ 5  

 

F-45


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Note 7 – Leases

Our leased assets consist primarily of land, tug vessels, a bridge, and office space and facilities, all of which are classified as operating leases, except for our tug vessels and bridge which are classified as finance leases.

The following table presents the line item classification of the Company’s right-of-use assets and lease liabilities on our Consolidated Balance Sheets (in millions):

 

          December 31,  
    

Line item

   2023      2022  

Right-of-use assets - operating

   Right-of-use assets    $ 381      $ 327  

Right-of-use assets - finance

   Property, plant and equipment, net      101        91  
     

 

 

    

 

 

 

Total right-of-use assets

      $ 482      $ 418  
     

 

 

    

 

 

 

Current operating lease liabilities

   Accrued and other liabilities    $ 13      $ 12  

Current finance lease liabilities

   Accrued and other liabilities      13        9  

Noncurrent operating lease liabilities

   Noncurrent operating lease liabilities      383        337  

Noncurrent finance lease liabilities

   Other noncurrent liabilities      75        78  
     

 

 

    

 

 

 

Total lease liabilities

      $ 484      $ 436  
     

 

 

    

 

 

 

The following table presents the line item classification of the Company’s lease costs (in millions):

 

    

Line item

   Years ended December 31,  
   2023      2022      2021  

Operating lease cost

   Operating and maintenance expense    $ 22      $ 16      $ 9  
   General and administrative expense      8        5        4  
   Development expense      19        15        7  

Finance lease cost

           

Amortization of right-of-use assets

   Depreciation and amortization and Property, plant and equipment, net      11        8        1  

Interest on lease liabilities

   Interest expense, net and Property, plant and equipment, net      6        6        1  

Short-term lease cost

   Cost of sales      —         35        —   
     

 

 

    

 

 

    

 

 

 

Total lease cost

      $ 66      $ 85      $ 22  
     

 

 

    

 

 

    

 

 

 

 

F-46


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Future annual minimum lease payments for operating and finance leases as of December 31, 2023 are as follows (in millions):

 

Years ended December 31,

   Operating leases      Finance leases  

2024

   $ 37      $ 18  

2025

     41        15  

2026

     38        12  

2027

     33        11  

2028

     31        11  

Thereafter

     736        48  
  

 

 

    

 

 

 

Total lease payments

   $ 916      $ 115  

Less: Interest

     (520      (27
  

 

 

    

 

 

 

Present value of lease liabilities

   $ 396      $ 88  
  

 

 

    

 

 

 

The following table presents the weighted-average remaining lease term (in years) and the weighted-average discount rate for the Company’s operating leases and finance leases:

 

     December 31,  
     2023     2022  
     Operating leases     Finance leases     Operating leases     Finance leases  

Weighted-average remaining lease term

     25.0       8.6       24.5       10.2  

Weighted-average discount rate

     7.4     6.7     6.4     6.8

Note 8 – Equity Method Investments

The following table presents the Company’s equity method investment ownership interests and carrying values (dollar amounts in millions):

 

     December 31, 2023  

Equity method investment (a)

   Ownership
interest
    Carrying
value
 

Kagami 1

     19   $ 110  

Kagami 2

     19     110  

Astra 5

     40     159  

Astra 8

     40     160  
    

 

 

 

Total

     $ 539  
    

 

 

 

 

(a)

These companies are VIEs in which the Company is not the primary beneficiary since it lacks the power to make significant decisions.

Kagami Companies

During the year ended December 31, 2023, the Company acquired equity interests in Project Kagami 1 Limited (“Kagami 1”) and Project Kagami 2 Limited (“Kagami 2,” and together with Kagami 1, the “Kagami Companies”). The Kagami Companies will each purchase one LNG tanker. The Company has future commitments to increase its investment in the Kagami Companies by $334 million to fund construction of the LNG tankers, which is subject to conditions precedent that have not yet been satisfied.

 

F-47


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Astra Companies

During the year ended December 31, 2023, the Company acquired equity interests in Astra 5 Limited (“Astra 5”) and Astra 8 Limited (“Astra 8,” and together with Astra 5, the “Astra Companies”). The Astra Companies will each purchase one LNG tanker. The Company has future commitments to increase its investment in the Astra Companies by $253 million to fund construction of the LNG tankers, which is subject to conditions precedent that have not yet been satisfied.

Note 9 – Accrued and Other Liabilities

Components of accrued and other liabilities included (in millions):

 

     December 31,  
     2023      2022  

Accrued construction and equipment costs

   $ 1,012      $ 671  

Accrued interest

     230        77  

Accrued natural gas purchases

     164        311  

Accrued compensation

     134        117  

Other

     161        168  
  

 

 

    

 

 

 

Total accrued and other liabilities

   $ 1,701      $ 1,344  
  

 

 

    

 

 

 

Note 10 – Asset Retirement Obligations

The following table summarizes the components of the Company’s asset retirement obligations (in millions):

 

     Years ended December 31,  
     2023      2022  

Beginning balance as of January 1

   $ 191      $ 17  

Liabilities incurred

     112        8  

Accretion expense

     14        1  

Revision in estimated cash flows

     94        165  
  

 

 

    

 

 

 

Ending balance as of December 31

   $ 411      $ 191  
  

 

 

    

 

 

 

Note 11 – Debt

The following table summarizes the Company’s outstanding debt (dollar amounts in millions):

 

                December 31,  
    

Maturity

   Interest rate (a)     2023      2022  

Fixed rate:

          

VGLNG 2028 Notes

   June 1, 2028      8.125   $ 2,250      $ —   

VGLNG 2029 Notes (b)

   February 1, 2029      9.500     3,000        —   

VGLNG 2031 Notes

   June 1, 2031      8.375     2,250        —   

VGLNG 2032 Notes (c)

   February 1, 2032      9.875     2,000        —   

Calcasieu Pass 2029 Notes

   August 15, 2029      3.875     1,250        1,250  

Calcasieu Pass 2030 Notes

   January 15, 2030      6.250     1,000        —   

Calcasieu Pass 2031 Notes

   August 15, 2031      4.125     1,250        1,250  

Calcasieu Pass 2033 Notes

   November 1, 2033      3.875     1,250        1,250  

 

F-48


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

                 December 31,  
    

Maturity

   Interest rate (a)      2023      2022  

Variable rate:

           

Calcasieu Pass Construction Term Loan

           1,174        2,305  

PL Holdings Credit Facility (d)

           727        —   

Plaquemines Construction Term Loan

           4,944        1,069  

VGLNG 2025 Term Loan

           —         3,300  

VGC 2024 Term Loan

           —         380  
        

 

 

    

 

 

 

Total outstanding debt

           21,095        10,804  
        

 

 

    

 

 

 

Less: Unamortized debt discount, premium and issuance costs

           (310      (196
        

 

 

    

 

 

 

Total outstanding debt, net

           20,785        10,608  

Less: Current portion of long-term debt

           (178      (150
        

 

 

    

 

 

 

Total long-term debt, net

         $ 20,607      $ 10,458  
        

 

 

    

 

 

 

 

(a)

Refer below for the rates associated with the respective variable rate debt instruments.

(b)

Issued in October and November 2023 at 100.167% of par.

(c)

Issued in October and November 2023 at 99.661% of par.

(d)

Refer to the credit facility discussion below for further information.

The aggregate contractual annual maturities for outstanding debt as of December 31, 2023 are as follows (in millions):

 

Years ended December 31,

   Contractual
maturities
 

2024

   $ 178  

2025

     917  

2026

     806  

2027

     238  

2028

     2,606  

Thereafter

     16,350  
  

 

 

 

Total

   $ 21,095  
  

 

 

 

VGLNG Senior Secured Notes

The VGLNG 2028 Notes, VGLNG 2029 Notes, VGLNG 2031 Notes, and VGLNG 2032 Notes are collectively referred to as the “VGLNG Senior Secured Notes”. The VGLNG Senior Secured Notes are secured on a pari passu basis by a first-priority security interest in substantially all of the existing and future assets of VGLNG and the future guarantors, if any. In addition, VGLNG has pledged its membership interests in certain material direct subsidiaries as collateral to secure its obligations under the VGLNG Senior Secured Notes. VGLNG may redeem all or part of the VGLNG Senior Secured Notes at specified prices set forth in the respective governing indenture agreements, plus accrued interest, if any, as of the date of the redemption.

Calcasieu Pass Senior Secured Notes

The Calcasieu Pass 2029 Notes, Calcasieu Pass 2030 Notes, Calcasieu Pass 2031 Notes, and Calcasieu Pass 2033 Notes are collectively referred to as the “Calcasieu Pass Senior Secured Notes”. The obligations of Calcasieu

 

F-49


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Pass under the Calcasieu Pass Senior Secured Notes are guaranteed by TransCameron and secured on a pari passu basis by a first-priority security interest in the assets that secure the Calcasieu Pass Credit Facility. Calcasieu Pass may redeem all or part of the Calcasieu Pass Senior Secured Notes at specified prices set forth in the respective governing indenture agreements, plus accrued interest, if any, as of the date of the redemption.

Credit Facilities

Below is a summary of the Company’s committed credit facilities outstanding as of December 31, 2023 (in millions):

 

    Calcasieu Pass Credit Facility (a)           Plaquemines Credit Facility (d)  
    Calcasieu Pass
Construction
Term Loan
    Calcasieu Pass
Working Capital
Facility
    PL Holdings
Credit Facility (c)
    Plaquemines
Construction
Term Loan
    Plaquemines
Working
Capital Facility
 

Original facility size

  $ 5,477       300     $ 1,665     $ 8,459     $ 1,100  

Incremental commitments

    —        255       —        4,489       1,000  

Less:

         

Outstanding balances

    1,174       —        727       4,944       —   

Commitments prepaid or terminated

    4,303       —        938       —        —   

Letters of credit issued

    —        339       —        —        840  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Available commitments

  $ —      $ 216     $ —      $ 8,004     $ 1,260  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Priority ranking

    Senior secured       Senior secured       Secured       Senior secured       Senior secured  

Interest rate on outstanding balances

   


SOFR(b)

+

2.375% to
2.875%

 

 

 
 

   


SOFR(b)

+

2.375% to
2.875%

 

 

 
 

   


SOFR

+

5.100% to
5.250%

 

 

 
 

   


SOFR

+

1.975% to
2.625%

 

 

 
 

   


SOFR

+

1.975% to
2.625%

 

 

 
 

    or       or       or       or       or  
   


base rate

+

1.375% to
1.875%

 

 

 
 

   


base rate

+

1.375% to
1.875%

 

 

 
 

   

base rate

+

4.000%

 

 

 

   


base rate

+

0.875% to
1.375%

 

 

 
 

   


base rate

+

0.875% to
1.375%

 

 

 
 

Commitment fees on undrawn balance

    0.831     0.919     —        0.656     0.656

Maturity date

    August 19, 2026       August 19, 2026       March 10, 2025       May 25, 2029       May 25, 2029  

 

(a)

The obligations of Calcasieu Pass as the borrower are guaranteed by TransCameron and secured by a first-priority lien on substantially all of the assets of Calcasieu Pass and TransCameron, as well as all of the membership interests in those companies.

(b)

During the year ended December 31, 2023, the Calcasieu Pass Credit Facility was modified to transition its variable rate interest from the London Interbank Offered Rate (“LIBOR”) to the U.S. Secured Overnight Financing Rate (“SOFR”). Calcasieu Pass elected to apply the expedient available under ASC 848, Reference Rate Reform to account for the modification as a continuation of the existing contract and not a debt modification.

(c)

The obligations of Plaquemines LNG Holdings, LLC (“PL Holdings”), a wholly-owned indirect subsidiary of Venture Global, are secured on a pari passu basis by a first-priority security interest in substantially all of the existing and future assets of PL Holdings. In addition, PL Holdings has pledged its membership interests as collateral to secure its obligations under the PL Holdings Credit Facility.

(d)

The obligations of Plaquemines as the borrower are guaranteed by Gator Express and secured by a first-priority lien on substantially all of the assets of Plaquemines and Gator Express, as well as all of the membership interests in those companies.

 

F-50


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Debt covenants

The Company’s debt instruments contain certain customary affirmative and negative covenants that among other things, limit our ability to incur additional indebtedness, create liens, dispose of assets, or pay dividends, distributions or other restricted payments. The Calcasieu Pass Credit Facility and the Plaquemines Credit Facility both include a financial covenant that requires the borrower to maintain a historical debt service coverage ratio of at least 1.15:1 as of the end of any fiscal quarter following the first term loan repayment date. As of December 31, 2023, each of our issuers was in compliance with all covenants related to their respective debt obligations.

The Calcasieu Pass and Plaquemines projects are restricted from making distributions under the agreements governing their respective indebtedness generally until, among other requirements, they have established the appropriate reserves and historical and projected debt service reserves. The restricted net assets of our consolidated subsidiaries was approximately $5.8 billion as of December 31, 2023.

Interest expense on debt

The following table presents the total interest expense incurred on the Company’s debt and other instruments (in millions):

 

     Years ended December 31,  
     2023      2022      2021  

Stated interest

   $ 1,038      $ 562      $ 226  

Amortization of debt discounts and issuance costs

     138        162        67  

Other interest and fees

     114        95        22  
  

 

 

    

 

 

    

 

 

 

Total interest cost

     1,290        819        315  

Capitalized interest

     (649      (227      (263
  

 

 

    

 

 

    

 

 

 

Total interest expense, net

   $ 641      $ 592      $ 52  
  

 

 

    

 

 

    

 

 

 

Note 12 – Derivatives

Interest rate swaps

The Company has entered into interest rate swaps to mitigate its exposure to variability in interest payments associated with certain variable rate debt.

During the year ended December 31, 2023, the Company received $83 million, net, from the settlement of a portion of the interest rate swaps associated with the Calcasieu Pass Credit Facility and the Plaquemines Credit Facility. In addition, the Company received $12 million from the full settlement of the interest rate swaps associated with the VGLNG 2025 Term Loan. Of the settlements, $41 million was associated with the termination of Calcasieu Pass Credit Facility interest rate swaps designated as cash flow hedges and therefore was deferred in AOCL and will be recognized in earnings at the time the originally forecasted hedged transaction impacts earnings. The Company did not re-designate the remaining notional amounts of the interest rate swaps previously designated as cash flow hedges.

 

F-51


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

The following table summarizes the Company’s outstanding interest rate swaps (dollar amounts in millions):

 

                               Outstanding notional  
                               December 31,  

Debt instrument

   Latest
maturity
    Receive
variable rate
     Pay
fixed rate (c)
    Maximum
notional
     2023      2022  

Plaquemines Credit Facility

     2046 (a)      Compounding SOFR        2.49   $ 10,204      $ 5,059      $ 2,691  

Calcasieu Pass Credit Facility

     2036 (b)      Compounding SOFR        2.55     1,142        1,142        2,195  

VGLNG 2025 Term Loan

     2025      
1-month LIBOR and
Compounding SOFR
 
 
     2.04     —         —         250  
         

 

 

    

 

 

    

 

 

 
          $ 11,346      $ 6,201      $ 5,136  
         

 

 

    

 

 

    

 

 

 

 

(a)

Subject to mandatory early termination provisions under which certain interest rate swaps will settle at their fair values in May 2029.

(b)

Subject to mandatory early termination provisions under which certain interest rate swaps will settle at their fair values in August 2026.

(c)

Represents a weighted-average fixed rate based on the maximum notional.

The following table summarizes the fair value (in millions), classification and hedge designation of the Company’s derivatives on the Consolidated Balance Sheets as of December 31, 2023 and 2022:

 

        December 31,  
        2023     2022  
   

Balance sheet location

  Designated     Non-designated     Total     Designated     Non-designated     Total  

Assets

             

Interest rate swaps

  Derivative assets   $ —      $ 164     $ 164     $ 25     $ 121     $ 146  

Interest rate swaps

  Noncurrent derivative assets     —        899       899       61       912       973  
   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Total assets

    $ —      $ 1,063     $ 1,063     $ 86     $ 1,033     $ 1,119  
   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Liabilities

             

Interest rate swaps

  Accrued and other liabilities   $ —      $ 1     $ 1     $ —      $ 1     $ 1  

Interest rate swaps

  Other noncurrent liabilities     —        6       6       —        20       20  
   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Total liabilities

    $ —      $ 7     $ 7     $ —      $ 21     $ 21  
   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

 

F-52


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

The following table presents the pre-tax effects of the Company’s derivative instruments recognized in AOCL and earnings (in millions):

 

   

Line item

  Years ended December 31,  
  2023     2022     2021  

Designated as hedging instruments

       

Gains (losses) recognized in AOCL

       

Interest rate swaps

  Change in fair value   $ (10   $ 113     $ 70  

Reclassifications of losses from AOCL into earnings

       

Interest rate swaps

  Depreciation and amortization     2       1       —   

Interest rate swaps

  Interest expense, net     3       9       —   
   

 

 

   

 

 

   

 

 

 

Total

    $ 5     $ 10     $ —   
   

 

 

   

 

 

   

 

 

 

Not designated as hedging instruments — recognized in earnings

       

Interest rate swaps

  Gain on derivatives, net   $ 174     $ 1,212     $ 38  

Embedded derivative

  Gain (loss) on embedded derivative     —        (14     12  

Approximately $14 million is expected to be reclassified from AOCL as a reduction to earnings within the next twelve months.

The following table presents the gross and net fair value of the Company’s outstanding interest rate swaps (in millions):

 

     December 31,  
     2023     2022  
     Gross
balance
    Balance subject
to netting
     Net
balance
    Gross
balance
    Balance subject
to netting
    Net
balance
 

Derivative assets

   $ 1,063     $ —       $ 1,063     $ 1,132     $ (13   $ 1,119  

Derivative liabilities

     (7     —         (7     (34     13       (21

Credit-risk related contingent features

The interest rate swap agreements contain cross default provisions whereby if the Company were to default on certain indebtedness, it could also be declared in default on its derivative obligations and may be required to net settle the outstanding derivative liability positions with its counterparties. As of December 31, 2023, the Company had not posted any collateral related to these agreements and was not in breach of any agreement provisions. The aggregate fair value of our derivative instruments with credit-risk related contingent features in a net liability position was $7 million as of December 31, 2023.

 

F-53


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Note 13 – Fair Value Measurements

The following table presents the Company’s financial assets and liabilities measured at fair value on a recurring basis and indicates their levels within the fair value hierarchy (in millions):

 

     December 31,  
     2023      2022  
     Level 1      Level 2      Level 3      Total      Level 1      Level 2      Level 3      Total  

Assets

                       

Money market funds (a)

   $ 3,391      $ —       $ —       $ 3,391      $ 378      $ —       $ —       $ 378  

Interest rate swaps (b)

     —         1,063        —         1,063        —         1,132        —         1,132  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ 3,391      $ 1,063      $ —       $ 4,454      $ 378      $ 1,132      $ —       $ 1,510  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Liabilities

                       

Interest rate swaps (c)

   $ —       $ 7      $ —       $ 7      $ —       $ 34      $ —       $ 34  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ —       $ 7      $ —       $ 7      $ —       $ 34      $ —       $ 34  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

 

(a)

Included in Cash and cash equivalents on the Consolidated Balance Sheets.

(b)

Included in Derivative assets and Noncurrent derivative assets on the Consolidated Balance Sheets.

(c)

Included in Accrued and other liabilities and Other noncurrent liabilities on the Consolidated Balance Sheets.

Interest rate swaps

The fair values of the Company’s interest rate swaps are classified as Level 2 and determined using a discounted cash flow method that incorporates observable inputs. The fair value calculation includes a credit valuation adjustment and forward interest rate curves for the same periods of the future maturity dates of the interest rate swaps. For further discussion, see Note 12 – Derivatives.

Level 3 unobservable inputs

In June 2019, VGLNG issued a $460 million senior convertible note that contained embedded features subject to derivative accounting (the “2024 Convertible Note”). The fair value of the embedded derivative was determined as the difference between the fair value of the 2024 Convertible Note with and without the embedded derivative using a discounted cash flow model under which the future probability-weighted settlement scenarios were discounted from their respective potential settlement dates to the valuation date. The 2024 Convertible Note and its associated embedded derivative were modified and fully settled in December 2022.

 

F-54


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

The following table sets forth a reconciliation of changes in the fair value of the Company’s net derivative instruments measured at fair value on a recurring basis using Level 3 inputs for the year ended December 31, 2022 (in millions). There were no derivative instruments measured at fair value using Level 3 inputs during the year ended December 31, 2023.

 

     Year ended December 31, 2022  
     Interest
rate swaps
     Embedded
derivative
     Total  

Beginning balance as of January 1

   $ (57    $ (162    $ (219

Issuances (a)

     —         (16      (16

Settlements

     —         192        192  

Total realized and unrealized gain (loss):

        

Included in earnings

     190        (14      176  

Transfers of assets out of Level 3 (b)

     (133      —         (133
  

 

 

    

 

 

    

 

 

 

Ending balance as of December 31

   $ —       $ —       $ —   
  

 

 

    

 

 

    

 

 

 

Unrealized gain included in earnings

   $ 190      $ —       $ 190  

 

(a)

Represents interest paid-in-kind on the 2024 Convertible Note attributed to the embedded derivative.

(b)

Represents the transfer of Plaquemines Credit Facility interest rate swaps to Level 2 upon the removal of a certain deal contingent feature.

Other financial instruments

The following table presents the fair value of the Company’s outstanding debt instruments in the Consolidated Balance Sheets (in millions):

 

            December 31,  
     Level      2023      2022  

Fixed rate debt

     1      $ 14,098      $ 3,176  

Variable rate debt (a)

     2        6,845        7,054  

 

(a)

Carrying value approximates estimated fair value.

Note 14 – Income Taxes

The Company is a taxpayer in multiple jurisdictions within the U.S. The Company is also a taxpayer in certain international jurisdictions due to its limited operations outside the U.S.

 

F-55


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Income tax expense consisted of the following (in millions):

 

     Years ended
December 31,
 
     2023      2022      2021  

Current

        

Federal

   $ 133      $ —       $ —   

State

     6        —         —   

Foreign

     —         1        —   
  

 

 

    

 

 

    

 

 

 

Total current income tax expense

   $ 139      $ 1      $ —   
  

 

 

    

 

 

    

 

 

 

Deferred

        

Federal

     681        441        —   

State

     (4      5        —   
  

 

 

    

 

 

    

 

 

 

Total deferred income tax expense

     677        446        —   
  

 

 

    

 

 

    

 

 

 

Total income tax expense

   $ 816      $ 447      $ —   
  

 

 

    

 

 

    

 

 

 

The following is a reconciliation of the statutory federal income tax rate to the effective tax rate:

 

     Years ended December 31,  
     2023     2022     2021  

U.S. federal statutory tax rate

     21.0     21.0     21.0

State tax rate, net of federal tax benefit

     (0.3 )%      (0.5 )%      3.4

Change in valuation allowance

     0.8     (11.7 )%      (11.5 )% 

Change in tax rate

     (0.2 )%      (0.2 )%      (10.7 )% 

163(l) interest expense

         4.2     (5.0 )% 

Guaranteed payment

     (0.3 )%      (0.3 )%      2.7

Foreign derived intangible income (“FDII”) deduction

     (1.8 )%      —      — 

Stock-based compensation

     (0.8 )%      —      — 
  

 

 

   

 

 

   

 

 

 

Effective tax rate

     18.4     12.5     (0.1 )% 
  

 

 

   

 

 

   

 

 

 

Significant components of deferred tax assets and liabilities are included in the table below (in millions):

 

     December 31,  
     2023      2022  

Deferred tax assets

     

Lease liabilities

   $ 111      $ 102  

Net operating loss carryforwards

     174        1,063  

Stock-based compensation

     29        28  

Property, plant and equipment

     139        —   

Accrued expenses

     31        30  

Asset retirement obligations

     70        20  

Other deferred tax assets

     10        23  
  

 

 

    

 

 

 

Total deferred tax assets

     564        1,266  

Deferred tax liabilities

     

Derivative assets

     (251      (270

Outside basis in CP Holdings

     (1,256      (1,304

 

F-56


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

     December 31,  
     2023      2022  

Property, plant and equipment

     —         (4

Right-of-use assets

     (107      (96

Other deferred tax liabilities

     (3      (3
  

 

 

    

 

 

 

Total deferred tax liabilities

     (1,617      (1,677

Less: Valuation allowance

     (96      (63
  

 

 

    

 

 

 

Net deferred tax liabilities

   $ (1,149    $ (474
  

 

 

    

 

 

 

As of December 31, 2023, the Company had accumulated an outside basis taxable temporary difference for its investment in CP Holdings of $5.9 billion. This outside basis amount is primarily comprised of differences between the GAAP and tax basis of CP Holdings’ property, plant and equipment.

As of December 31, 2023, the Company had accumulated federal net operating loss carryforwards of $367 million with an indefinite carryforward period. As of December 31, 2023, the Company also had accumulated state net operating loss carryforwards of approximately $1.7 billion (after the application of state apportionment factors), of which $42 million will expire by 2037. Utilization of these net operating losses may be limited when there is an ownership change as defined by Section 382 of the Internal Revenue Code. As of December 31, 2023, the Company did not believe any of its net operating losses were limited under these rules.

Net operating losses may also be limited when there is a separate return limitation year (“SRLY”). These rules generally limit the use of net operating loss carryforwards to the amount of taxable income that the net operating loss-producing entity contributes to the consolidated group’s taxable income. Net operating losses subject to the SRLY rules may also be subject to Section 382 limitations. Of the $367 million federal net operating loss carryforward as of December 31, 2023, $42 million is currently subject to the SRLY rules.

The Company maintains a valuation allowance against its federal deferred tax assets related to its SRLY tax attributes and its state deferred tax assets for which it continues to believe the more-likely-than-not recognition threshold has not been met. The Company’s valuation allowances increased by $33 million during the year to $96 million as of December 31, 2023. This increase was primarily due to state valuation allowance activity.

As of December 31, 2023 and 2022, the Company had no unrecognized tax benefits and did not recognize any interest or penalties during those respective periods.

The Company remains subject to examination of its U.S. federal and state income tax returns for the tax years ended 2019 through 2023. Tax authorities may have the ability to review and adjust carryover tax attributes that were generated prior to these periods.

On August 16, 2022, the Inflation Reduction Act of 2022 (“IRA”) was enacted in the U.S. The IRA included a 15% alternative minimum tax on the “adjusted financial statement income” of certain corporations and a 1% excise tax on stock repurchases, both of which became effective in 2023. These provisions did not have a material impact to the Company’s financial statements.

The Organization Economic Co-operation and Development (“OECD”) introduced Base Erosion and Profit Shifting (“BEPS”) Pillar 2 rules that impose a global minimum tax rate of 15%. Numerous countries, including European Union member states, have enacted legislation to be effective as early as January 1, 2024, with general implementation of a global minimum tax by January 1, 2025. The Company is continuing to evaluate the potential impact on its consolidated financial statements, as further guidance becomes available.

 

F-57


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Note 15 – Commitments and Contingencies

The following is a schedule of the Company’s future minimum commitments as of December 31, 2023 (in millions):

 

Years ended December 31,

   Natural gas
supply
     Firm
transportation
     LNG tankers      Other      Total  

2024

   $ 1,166      $ 145      $ 141      $ 59      $ 1,511  

2025

     1,781        352        632        34        2,799  

2026

     1,457        400        288        9        2,154  

2027

     1,115        400        —         5        1,520  

2028

     880        400        —         5        1,285  

Thereafter

     962        6,288        —         21        7,271  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ 7,361      $ 7,985      $ 1,061      $ 133      $ 16,540  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Natural gas supply

The Company has entered into natural gas forward purchase contracts for the supply of feed gas to the Calcasieu Pass Project and the Plaquemines Project. The Company intends to take physical delivery of the contracted quantities through March 2030, at a purchase price indexed to the Henry Hub price for natural gas. The Company has designated the natural gas forward contracts as normal purchase and normal sale transactions exempted from derivative accounting treatment.

Firm transportation agreements

The Company has entered into long-term natural gas firm transportation service agreements with various interstate pipeline companies to secure the natural gas transportation requirements for the Calcasieu Pass Project and the Plaquemines Project through June 2045.

LNG tankers

The Company has entered into shipbuilding agreements for the construction of five LNG tankers, excluding commitments for our equity method investments discussed in Note 8 – Equity Method Investments. The LNG tankers will be used to provide shipping capabilities to our LNG projects upon their deliveries beginning in July 2025.

Litigation

The Company is involved in certain claims, suits, and legal proceedings in the normal course of business. The Company accrues for litigation and claims when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. There can be no assurance that these accrued liabilities will be adequate to cover all existing and future claims or that we will have the liquidity to pay such claims as they arise.

Where no accrued liability has been recognized, it is reasonably possible that some matters could be decided unfavorably to the Company. This could require the Company to pay damages or make expenditures in amounts that could be material but could not be estimated as of December 31, 2023. Contingencies where losses are reasonably possible primarily relate to disputes with contractors. Damages from our disputes with contractors could range from zero up to approximately $200 million. See Note 4 – Revenue from Contracts with Customers, for further discussion of the disputes with customers.

 

F-58


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Note 16 – Equity

During the year ended December 31, 2022, the Company’s consolidated subsidiary, VGLNG, repurchased 55,000 shares of its Series B common stock and 23,700 shares of its Series C common stock for $1.4 billion. This was recognized as a $1.0 billion and $0.4 billion reduction to members’ capital and non-controlling interests, respectively. In addition, during the year ended December 31, 2023, prior to the Reorganization Transactions, VGLNG repurchased 5,000 shares of its Series B common stock and 81,896 shares of its Series C common stock for $1.6 billion. This was recognized as a $1.2 billion and $0.4 billion reduction to stockholders’ equity and non-controlling interests, respectively.

In September 2023, in connection with the Reorganization Transactions, Venture Global completed the 2023 Merger whereby Legacy VG Partners merged with and into Venture Global, with VG Partners receiving 435,500 shares of Venture Global’s Class A common stock in exchange for its equity interests in Legacy VG Partners.

In addition, as part of the Reorganization Transactions, the VGLNG non-controlling shareholders holding 84,272 shares of VGLNG’s Series C common stock received 84,272 shares of Venture Global’s Class A common stock, in a one-for one exchange.

Upon completion of the Reorganization Transactions in September 2023, all shares of VGLNG’s Series A, Series B and Series C common stock were owned and subsequently retired by the Company, resulting in a $2.0 billion reduction to retained earnings.

The following table summarizes the number of shares of the Company’s preferred stock and common stock authorized for issuance and outstanding by class as of December 31, 2023:

 

     Authorized      Outstanding  

Preferred stock

     1,000,000        —   

Class A common stock

     1,000,000        519,772  

Class B common stock

     1,000,000        —   

Each class of stock is subject to a shareholders’ agreement. The holders of the Class A common stock common stockholders are entitled to one vote per share.

Note 17 – Redeemable Stock of Subsidiary

In August 2019, the Company issued nine million redeemable preferred units in CP Funding with an initial face value of $100 per preferred unit (the “Redeemable Preferred Units”). The Redeemable Preferred Units are redeemable at the Company’s option or, following the eighth anniversary of the date of issuance, to the extent the Company has available cash as defined within CP Funding’s ownership agreement. The Redeemable Preferred Units have an aggregate liquidation preference of $900 million plus accrued or paid-in-kind distributions and an additional premium if liquidation occurs during the first six years after the date of issuance or if redemption occurs during years four through six after the date of issuance. The Redeemable Preferred Units are not convertible to common units or any other classes of interests and have no voting rights, except with respect to certain matters that require approval from the holders of the Redeemable Preferred Units.

The Redeemable Preferred Units pay cumulative, quarterly distributions at an initial rate of 10.0% per annum. Distributions can be paid in cash or in-kind by increasing the face value of the Redeemable Preferred Units. The distribution rate increases by 0.5% upon the eighth anniversary of the date of issuance and every six months thereafter up to a maximum rate of 15.0% per annum. Distributions paid in-kind following COD for the Calcasieu Pass Project are subject to an additional 1.0% distribution.

 

F-59


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

The Redeemable Preferred Units are carried at their redemption value and presented as Redeemable stock of subsidiary on the Consolidated Balance Sheets. The following table summarizes the change in Redeemable stock of subsidiary on the Consolidated Balance Sheets (in millions):

 

     Years ended December 31,  
     2023      2022  

Beginning balance as of January 1

   $ 1,255      $ 1,137  

Paid-in-kind distributions (a)

     130        118  
  

 

 

    

 

 

 

Ending balance as of December 31

   $ 1,385      $ 1,255  
  

 

 

    

 

 

 

 

(a)

Presented as Net income attributable to redeemable stock of subsidiary on the Consolidated Statements of Operations.

Note 18 – Non-Controlling Interests

VGLNG

During the years ended December 31, 2023 and 2022, and prior to the Reorganization Transactions, VGLNG repurchased shares of its Series B and Series C common stock. This was recognized as a reduction to stockholders’ equity and non-controlling interests. As part of the NCI Acquisition, the remaining non-controlling VGLNG shareholders exchanged their shares of common stock of VGLNG for shares of Class A common stock of Venture Global. See Note 1 – The Company and Note 16 – Equity for further discussion.

CP Holdings

In August 2019, CP Holdings issued four million convertible preferred units in CP Holdings with an initial face value of $100 per preferred unit (the “Convertible Preferred Units”). The Convertible Preferred Units are convertible into Class B common units of CP Holdings based on a prescribed conversion ratio. Conversion is automatic upon COD of the Calcasieu Pass Project, or, at the option of the holder of the Convertible Preferred Units, upon liquidation or change of control in CP Holdings or its subsidiaries. On a liquidation or change of control event, the holder of the Convertible Preferred Units also has the option to redeem the Convertible Preferred Units at the aggregate liquidation preference of $400 million plus accrued distributions.

The Convertible Preferred Units pay a cumulative quarterly distribution at an initial rate of 10.0% per annum recognized as Net income attributable to non-controlling interests. Distributions can be paid in cash or in-kind by increasing the face value of the Convertible Preferred Units prior to conversion. The distribution rate increases by 0.5% upon the eighth anniversary of the date of issuance and every six months thereafter up to a maximum rate of 15.0% per annum. The conversion ratio of the Convertible Preferred Units was approximately 23% of CP Holdings’ total outstanding common units as of December 31, 2023.

The following table summarizes the change in the Convertible Preferred Units (dollar amounts in millions):

 

     Years ended December 31,  
     2023      2022      2021  

Beginning balance as of January 1

   $ 547      $ 494      $ 447  

Net income attributable to non-controlling interests

     57        53        47  

Distributions

     (29      —         —   
  

 

 

    

 

 

    

 

 

 

Ending balance as of December 31

   $ 575      $ 547      $ 494  
  

 

 

    

 

 

    

 

 

 

 

F-60


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Note 19 – Stock-Based Compensation

In connection with the Reorganization Transactions, on September 25, 2023, the Company adopted the 2023 Stock Option Plan (the “2023 Plan”) which replaced the 2014 Stock Option Plan (the “Predecessor Plan”). Under the 2023 Plan, options outstanding to purchase 86,664 shares of VGLNG’s Series A common stock were automatically converted, on a one-for-one basis, in accordance with and pursuant to the terms of the Predecessor Plan, into options to purchase shares of the Company’s Class A common stock subject to the terms and conditions of the 2023 Plan. There are no other differences between the terms and conditions of the 2023 Plan and the Predecessor Plan. The 2023 Plan provides for the issuance of 95,000 shares of the Company’s Class A common stock.

Stock option activity

A summary of stock-based compensation activity for the years ended December 31, 2023, 2022 and 2021 is presented below:

 

    Options     Weighted
average
exercise price
    Exercise price range     Weighted
average
remaining
contractual life
(in years)
    Aggregate
intrinsic value

(in millions)
 

Outstanding at December 31, 2020

    73,133     $ 3,430     $ 1 to $7,000      

Granted

    5,700     $ 7,868     $ 7,000 to $10,000      

Exercised

    —           

Forfeited or expired

    (360   $ 5,571     $ 3,568 to $7,000      
 

 

 

   

 

 

       

Outstanding at December 31, 2021

    78,473     $ 3,743     $ 1 to $10,000      

Granted

    9,000     $ 14,933     $ 12,000 to $15,300      

Exercised

    —           

Forfeited or expired

    (2,557   $ 3,193     $ 2,000 to $7,000      
 

 

 

   

 

 

       

Outstanding at December 31, 2022

    84,916     $ 4,945     $ 1 to $15,300      

Granted

    700     $ 18,814     $ 18,000 to $23,700      

Exercised

    —           

Forfeited or expired

    (17,820   $ 1,286     $ 1 to $7,000      
 

 

 

   

 

 

       

Outstanding at December 31, 2023

    67,796     $ 6,106     $ 2.50 to $23,700       4.9     $ 1,566  

Exercisable at December 31, 2023

    58,265     $ 5,130     $ 2.50 to $23,700       4.5     $ 1,402  

The Black-Scholes fair value of the stock options granted during the years ended December 31, 2023, 2022 and 2021 was determined using the following assumptions:

 

    Years ended December 31,  
    2023     2022     2021  
    Weighted
average
    Range     Weighted
average
    Range     Weighted
average
    Range  

Expected life (a)

    6.1 years       6.1 years       6.1 years       6.1 years       6.1 years       6.1 years  

Risk-free interest rate (b)

    4.1%       3.6% to 4.6%       3.0%       2.4% to 4.0%       1.1%       1.0% to 1.4%  

Expected volatility (c)

    40.2%       40.1% to 40.4%       37.3%       37.1% to 38.6%       38.8%       37.7% to 38.9%  

Expected dividend yield

    — %       — %       — %       — %       — %       — %  

 

(a)

Computed using the simplified method based on the mid-point between the vesting and contractual terms since the Company did not have sufficient historical information to estimate the expected life.

 

F-61


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

(b)

The risk-free rate is based on U.S. Treasury bonds issued with similar maturity dates to the expected life of the grant.

(c)

Expected volatility is based on a weighted measure of historical, implied and expected volatility of comparable companies in the Company’s industry sector.

The options granted during the years ended December 31, 2023, 2022 and 2021, were granted at exercise prices equal to the fair market value of VGLNG’s Series A common stock on the respective grant dates. No options were granted under the new 2023 Plan during the year ended December 31, 2023. The options have a 10-year term and vest in equal quarterly installments over a four-year service period, subject to continued service through each vesting date. The weighted average grant-date fair value of options granted during the years ended December 31, 2023, 2022, and 2021 were $8,594, $6,197, and $3,048, respectively.

The classification of stock-based compensation expense by line item in the Company’s Consolidated Statements of Operations is as follows (in millions):

 

     Years ended
December 31,
 
  

 

 

 
     2023      2022      2021  

General and administrative expense

   $ 19      $ 25      $ 20  

Operating and maintenance expense

     6        —         —   

Development expense

     3        —         —   
  

 

 

    

 

 

    

 

 

 

Total stock-based compensation expense

   $ 28      $ 25      $ 20  
  

 

 

    

 

 

    

 

 

 

A tax benefit of $28 million related to stock-based compensation expense was recognized during the year ended December 31, 2023. No income tax benefit related to stock-based compensation expense was recognized during the years ended December 31, 2022 and 2021.

During the year ended December 31, 2023, the Company paid $152 million to settle a subset of fully vested options. The cash settlement did not constitute a modification of the awards or result in additional stock-based compensation expense.

As of December 31, 2023, there remained $47 million of total unrecognized compensation cost related to non-vested stock-based compensation grants. The Company expects this expense to be recognized over a weighted-average period of approximately 2.2 years.

 

F-62


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Note 20 – Earnings (Loss) per Share

The following table sets forth the computation of net income (loss) per share attributable to the Company’s Class A common stock outstanding (in millions, except share and per share amounts). The number of weighted average shares outstanding prior to the 2023 Merger were calculated based on the one-for-one exchange ratio of 435,500 shares of the Company’s Class A common stock issued to VG Partners in exchange for 100% of the Legacy VG Partners members’ equity interests in connection with the 2023 Merger:

 

     Years ended December 31,  
     2023      2022      2021  

Net income (loss)

   $ 3,616      $ 3,097      $ (436

Less: Net income attributable to redeemable stock of subsidiary

     130        118        107  

Less: Net income (loss) attributable to non-controlling interests

     805        1,121        (187
  

 

 

    

 

 

    

 

 

 

Net income (loss) attributable to common stockholders

   $ 2,681      $ 1,858      $ (356
  

 

 

    

 

 

    

 

 

 

Weighted average shares of common stock outstanding

        

Basic

     457,896        435,500        435,500  

Dilutive stock options outstanding (a)

     16,137        —         —   
  

 

 

    

 

 

    

 

 

 

Diluted

     474,033        435,500        435,500  
  

 

 

    

 

 

    

 

 

 

Net income (loss) attributable to common stockholders per share—basic

   $ 5,855      $ 4,266      $ (817

Net income (loss) attributable to common stockholders per share—diluted

   $ 5,656      $ 4,266      $ (817

 

(a)

Venture Global had no outstanding stock options prior to the adoption of the 2023 Plan in September 2023. See Note 19 – Stock-Based Compensation for further discussion.

Note 21 – Related Parties

The Company has a management services agreement with VG Partners. The Company incurred $2 million in connection with this agreement during the year ended December 31, 2023, which was recognized as General and administrative expense on the Consolidated Statements of Operations.

 

F-63


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Note 22 – Supplemental Cash Flow Information

The following table sets forth supplemental disclosure of cash flow information (in millions):

 

     Years ended December 31,  
  

 

 

 
     2023      2022      2021  

Accrued purchases of property, plant and equipment

   $ 1,248      $ 763      $ 308  

Cash paid for interest, net of amounts capitalized

     368        220        1  

Asset retirement obligation additions and revisions

     206        173        10  

Cash paid for income taxes

     127        —         —   

Paid-in-kind distribution on redeemable stock of subsidiary

     130        118        107  

Paid-in-kind distribution on non-controlling interests

     28        52        48  

Paid-in-kind interest on debt

     37        78        71  

Accrued distribution to non-controlling interests

     15        —         —   

Cash paid for operating leases

     45        29        9  

Right-of-use assets in exchange for new operating lease liabilities

     90        61        139  

Right-of-use assets in exchange for new finance lease liabilities

     10        1        90  

Note 23 – Segment Information

The Company has five operating segments, including our four LNG projects – the Calcasieu Pass Project, the Plaquemines Project, the CP2 LNG Project and the Delta LNG Project – and Shipping. Each LNG project operating segment includes activity of both the respective liquefaction facility and export terminal and the associated pipeline(s) that will supply the natural gas to that facility. The Company’s chief operating decision maker (“CODM”) is the Company’s Chief Executive Officer. The CODM allocates resources, assesses performance and manages the business according to these five operating segments. The Company’s performance is evaluated based on income (loss) from operations of the respective segment.

The Company has three reportable segments, the Calcasieu Pass Project, the Plaquemines Project, and the CP2 LNG Project. The Delta LNG Project and Shipping are not quantitatively material for reporting purposes and as such, have been combined with corporate activities as Corporate and other.

Activities reported in Corporate and other include immaterial operating segments, costs which are overhead in nature and not directly associated with the LNG projects and shipping activities, including certain general and administrative and marketing expenses, and inter-segment eliminations.

The Company attributes revenues from external customers by selling location. All revenue and the majority of long-lived assets were attributed to or located in the United States. Certain assets related to our shipping activities are located outside the United States.

 

F-64


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

The following tables present financial information by segment and a reconciliation of the Company’s segment Income (loss) from operations to Income before income tax expense on the Consolidated Statements of Operations for the periods indicated (in millions):

 

     Years ended December 31,  
Revenue    2023      2022      2021  

Calcasieu Pass Project

   $ 7,897      $ 6,448      $  —   

 

     Years ended December 31,  
Income (loss) from operations    2023      2022      2021  

Calcasieu Pass Project

   $ 5,598      $ 4,042      $ (85

Plaquemines Project

     (187      (269      (158

CP2 LNG Project

     (362      (34      (15

Corporate and other

     (199      (184      (79
  

 

 

    

 

 

    

 

 

 

Total income (loss) from operations

     4,850        3,555        (337
  

 

 

    

 

 

    

 

 

 

Interest income

     172        18        —   

Interest expense, net

     (641      (592      (52

Gain on derivatives, net

     174        1,212        38  

Gain (loss) on embedded derivative

     —         (14      12  

Loss on financing transactions

     (123      (635      (97
  

 

 

    

 

 

    

 

 

 

Income (loss) before income tax expense

   $ 4,432      $ 3,544      $ (436
  

 

 

    

 

 

    

 

 

 

 

     Total assets  
As of December 31,    2023      2022  

Calcasieu Pass Project

   $ 7,571      $ 7,652  

Plaquemines Project

     12,734        6,174  

CP2 LNG Project

     1,359        21  

Corporate and other

     6,799        1,250  
  

 

 

    

 

 

 

Total

   $ 28,463      $ 15,097  
  

 

 

    

 

 

 

 

     Capital expenditures      Depreciation and amortization  
Years ended December 31,    2023      2022      2021      2023      2022      2021  

Calcasieu Pass Project

   $ 98      $ 1,666      $ 1,970      $ 256      $ 144      $ 2  

Plaquemines Project

     6,351        2,948        70        —         —         —   

CP2 LNG Project

     831        —         —         —         —         —   

Corporate and other

     875        100        39        21        14        4  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total

   $ 8,155      $ 4,714      $ 2,079      $ 277      $ 158      $ 6  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

 

F-65


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

The following table presents the Company’s revenue from individual external customers that were 10% or greater than total revenue:

 

     Years ended
December 31,
 
     2023     2022     2021  

Customer A

     33     19     *  

Customer B

     17     12     *  

Customer C

     13     *       *  

Customer D

     11     *       *  

Customer E

     *       19     *  

Customer F

     *       13     *  

Customer G

     *       12     *  

 

(*)

Less than 10%.

Note 24 – Recent Accounting Pronouncements

The following table provides a description of recently issued accounting pronouncements that have not yet been adopted by the Company as of December 31, 2023. Accounting pronouncements not listed below were assessed and determined to not have a material impact to the Company’s consolidated financial statements.

 

Standard

  

Description

  

Effect on our Consolidated Financial
Statements

ASU 2023-07, Segment Reporting (Topic 280)   

In November 2023, the FASB issued ASU 2023-07, which improves reportable segment disclosure requirements. This requires disclosure about significant segment expenses regularly provided to the CODM, extending certain annual disclosures to interim periods, clarifying that single reportable segment entities must comply with ASC 280, permitting more than one measure of segment profit or loss to be reported under certain conditions, and disclosing the title and position of the CODM.

 

The standard is effective for fiscal years beginning after December 15, 2023, and interim periods within fiscal years beginning after December 15, 2024. Early adoption is permitted. The standard should be applied on a retrospective basis.

   The Company is currently evaluating the impact on our financial statement disclosures.
ASU 2023-09, Income Taxes (Topic 740)    In December 2023, the FASB issued ASU 2023-09, which enhances tax- related disclosures by requiring public business entities to disclose a tabular reconciliation, using both percentages and amounts, broken into specific categories with certain reconciling items at or above 5% of the statutory (i.e., expected) tax, further broken out by nature and/or jurisdiction;    The Company is currently evaluating the impact on our financial statement disclosures.

 

F-66


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONSOLIDATED FINANCIAL STATEMENTS

 

Standard

  

Description

  

Effect on our Consolidated Financial
Statements

  

for all other entities, qualitative disclosure of the nature and effect of significant reconciling items by specific categories and individual jurisdictions; and income taxes paid (net of refunds received), broken out between federal (national), state/local and foreign, and amounts paid to an individual jurisdiction when 5% or more of the total income taxes paid.

 

The standard is effective for fiscal years beginning after December 15, 2024, and interim periods within fiscal years beginning after December 15, 2025. Early adoption is permitted. The standard should be applied on a prospective basis, and retrospective application is permitted.

  

Note 25 – Subsequent Events

Management has evaluated subsequent events after the balance sheet date and through the date of issuance of the consolidated financial statements, February 22, 2024, for appropriate accounting and disclosure. The Company has determined that there were no such events that warrant disclosure or recognition in the consolidated financial statements except for the following:

On January 26, 2024, the DOE announced a temporary pause on pending approvals of LNG exports to non-FTA nations so it can review the analysis used to determine whether the export of LNG is in the public interest. Under the Natural Gas Act, the DOE is required to issue an order authorizing LNG exports upon application unless, after opportunity for hearing, it finds that the proposed exports will not be consistent with the public interest. The pause in approvals by the DOE could potentially result in a delay in obtaining approvals to export LNG to non-FTA nations for future projects.

 

F-67


Table of Contents

Report of Independent Registered Public Accounting Firm

To the Shareholders and Board of Directors of Venture Global, Inc.

We have audited the consolidated financial statements of Venture Global, Inc. (the Company) as of December 31, 2023 and 2022, for each of the three years in the period ended December 31, 2023, and have issued our report thereon dated February 22, 2024 included elsewhere in this Form S-1. Our audits of the consolidated financial statements included the financial information included in the financial statement schedule listed in Item 16(b) of this Form S-1 (the “schedule”). This schedule is the responsibility of the Company’s management. Our responsibility is to express an opinion on the Company’s schedule, based on our audits.

In our opinion, the schedule presents fairly, in all material respects, the information set forth therein when considered in conjunction with the consolidated financial statements.

/s/ Ernst & Young LLP

Tysons, VA

February 28, 2024

 

F-68


Table of Contents

VENTURE GLOBAL, INC.

SCHEDULE I CONDENSED FINANCIAL INFORMATION OF PARENT

BALANCE SHEETS

($ in millions)

 

     December 31,  
     2023      2022  

ASSETS

     

Current assets

     

Cash

   $ —       $ —   

Accounts receivable from subsidiary

     —         1  
  

 

 

    

 

 

 

Total current assets

     —         1  
  

 

 

    

 

 

 

Property, plant and equipment, net

     3        —   

Right-of-use assets

     3        3  

Investment in subsidiaries, net

     1,512        36  
  

 

 

    

 

 

 

TOTAL ASSETS

   $ 1,518      $ 40  
  

 

 

    

 

 

 

LIABILITIES AND EQUITY (DEFICIT)

     

Current liabilities

     

Accounts payable

   $ 2      $ —   

Accrued and other liabilities

     —         6  

Accounts payable to subsidiary

     3        11  
  

 

 

    

 

 

 

Total current liabilities

     5        17  
  

 

 

    

 

 

 

Long-term debt, net

     —         206  

Operating lease liabilities

     3        3  
  

 

 

    

 

 

 

Total liabilities

     8        226  
  

 

 

    

 

 

 

Equity

     

Stockholders’ and members’ equity (deficit)

     1,510        (186
  

 

 

    

 

 

 

TOTAL LIABILITIES AND EQUITY (DEFICIT)

   $ 1,518      $ 40  
  

 

 

    

 

 

 

See the accompanying notes to Schedule I.

 

F-69


Table of Contents

VENTURE GLOBAL, INC.

SCHEDULE I CONDENSED FINANCIAL INFORMATION OF PARENT

STATEMENTS OF OPERATIONS

($ in millions)

 

     Years ended December 31,  
     2023     2022     2021  

MANAGEMENT FEE FROM SUBSIDIARIES

   $ 5     $ 6     $ 6  
  

 

 

   

 

 

   

 

 

 

OPERATING EXPENSE

      

General and administrative expense

     2       2       1  
  

 

 

   

 

 

   

 

 

 

Total operating expense

     2       2       1  
  

 

 

   

 

 

   

 

 

 

INCOME FROM OPERATIONS

     3       4       5  

OTHER EXPENSE

      

Interest expense, net

     (29     (28     (7
  

 

 

   

 

 

   

 

 

 

Total other expense

     (29     (28     (7
  

 

 

   

 

 

   

 

 

 

LOSS BEFORE INCOME TAXES AND EQUITY INCOME (LOSS) OF SUBSIDIARIES

     (26     (24     (2

Less: income tax expense

     —        —        —   

Add: equity in income (loss) of subsidiaries, net of income taxes

     2,707       1,882       (354
  

 

 

   

 

 

   

 

 

 

NET INCOME (LOSS)

   $ 2,681     $ 1,858     $ (356
  

 

 

   

 

 

   

 

 

 

See the accompanying notes to Schedule I.

 

F-70


Table of Contents

VENTURE GLOBAL, INC.

SCHEDULE I CONDENSED FINANCIAL INFORMATION OF PARENT

STATEMENTS OF CASH FLOWS

($ in millions)

 

     Years ended December 31,  
       2023         2022         2021    

OPERATING ACTIVITIES

   $ 6     $ 5     $ 7  

INVESTING ACTIVITIES

      

Purchases of property, plant and equipment

     (1     —        —   
  

 

 

   

 

 

   

 

 

 

Net cash used by investing activities

     (1     —        —   
  

 

 

   

 

 

   

 

 

 

FINANCING ACTIVITIES

      

Proceeds from issuance of debt

     115       —        189  

Distributions from subsidiaries

     71       —        —   

Purchase of subsidiary interests

     —        —        (185

Payments of financing and issuance costs

     (42     —        (4

Distributions to members

     (149     (6     (7
  

 

 

   

 

 

   

 

 

 

Net cash used by financing activities

     (5     (6     (7
  

 

 

   

 

 

   

 

 

 

Net decrease in cash

     —        (1     —   

Cash at beginning of period

     —        1       1  
  

 

 

   

 

 

   

 

 

 

CASH AT END OF PERIOD

   $ —      $ —      $ 1  
  

 

 

   

 

 

   

 

 

 

See the accompanying notes to Schedule I.

 

F-71


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED FINANCIAL INFORMATION OF PARENT

Note 1 – Basis of presentation

The Condensed Financial Statements represent the financial information required by the Securities and Exchange Commission Regulation S-X 5-04 for Venture Global, Inc. (“Venture Global” or “the Parent Company”). Venture Global was formed by the managing members of Venture Global Partners II, LLC (“VG Partners”) on September 19, 2023 under the name of Venture Global Holdings, Inc. In January 2024, the Parent Company changed its name from Venture Global Holdings, Inc. to Venture Global, Inc.

In September 2023, Venture Global was party to certain reorganization transactions (the “Reorganization Transactions”) whereby Venture Global Partners, LLC (“Legacy VG Partners”), a then wholly-owned subsidiary of VG Partners and the controlling shareholder of Venture Global LNG, Inc. (“VGLNG”), merged with and into Venture Global (the “2023 Merger”), with VG Partners receiving 435,500 shares of Venture Global’s Class A common stock in exchange for 100% of its equity interests in Legacy VG Partners. In connection with the Reorganization Transactions, the non-controlling VGLNG shareholders, holding 84,272 shares of VGLNG’s issued and outstanding Series C common stock, received 84,272 shares of Class A common stock of Venture Global, in a one-for-one exchange for their shares of VGLNG (the “NCI Acquisition”). All shares of Series A, Series B and Series C common stock of VGLNG were retired upon completion of the Reorganization Transactions in September 2023. No cash was exchanged as part of the Reorganization Transactions and Venture Global incurred $40 million of third-party transaction costs in connection with its formation and the issuance of its shares of Class A common stock.

The 2023 Merger was accounted for as a transaction between entities under common control. Prior to the 2023 Merger, Venture Global, as a standalone entity, had no operations and had no assets or liabilities. The financial results and other information included in the Condensed Financial Statements for periods prior to the Reorganization Transactions were applied on a retrospective basis and are reflective of VG Partners.

In the Condensed Financial Statements, the Parent Company’s investment in subsidiaries are presented at the net amount attributable to Venture Global under the equity method of accounting. Under this method, the assets and liabilities of affiliates are not consolidated. The investments in net assets of the affiliates are reflected on the Condensed Balance Sheets. The net income or loss from operations of the subsidiaries is reported in equity or loss in income of subsidiaries, excluding income or loss from non-controlling interests.

A substantial amount of Venture Global’s operating, investing and financing activities are conducted by its affiliates. The Condensed Financial Statements should be read in conjunction with Venture Global’s Consolidated Financial Statements.

Note 2 – Investment in Subsidiaries

In December 2022, VGLNG, the Parent Company’s partially owned subsidiary, repurchased 55,000 Series B and 23,700 Series C shares of its common stock for $1.4 billion. VGLNG’s repurchase of its outstanding common stock increased Venture Global’s controlling interest in the subsidiary to 71.8% and was accounted for as an equity transaction. To reflect this change in ownership interest, the Parent Company recognized a $923 million decrease to Investment in subsidiaries for the year ended December 31, 2022.

In addition, during the year ended December 31, 2023, prior to the Reorganization Transactions, VGLNG repurchased 5,000 shares of its Series B common stock and 81,896 shares of its Series C common stock for $1.6 billion. VGLNG’s repurchase of its outstanding common stock increased Venture Global’s controlling interest in the subsidiary to 83.8% and was accounted for as an equity transaction. To reflect this change in ownership interest, the Parent Company recognized a $1.1 billion decrease to Investment in subsidiaries for the year ended December 31, 2023.

 

F-72


Table of Contents

VENTURE GLOBAL, INC.

NOTES TO THE CONDENSED FINANCIAL INFORMATION OF PARENT

 

After the Reorganization Transactions, Venture Global owned 100% of VGLNG. See Note 1 – Basis of presentation for further discussion.

Note 3 – Debt

The following table summarizes the Parent Company’s outstanding debt (in millions):

 

     December 31,  
     2023      2022  

Fixed rate:

     

VGC 2024 Term Loan

   $ —       $ 205  
  

 

 

    

 

 

 

Total outstanding debt

     —         205  
  

 

 

    

 

 

 

Plus: unamortized debt discount and issuance costs

     —         1  
  

 

 

    

 

 

 

Total outstanding debt, net

     —         206  

Less: current portion of long-term debt

     —         —   
  

 

 

    

 

 

 

Total long-term debt, net

   $ —       $ 206  
  

 

 

    

 

 

 

VGC 2024 Term Loan

In August 2021, Legacy VG Partners and Venture Global Commodities, LLC (“VGC”), as co-borrowers, entered into a senior secured term loan facility due August 2024 (the “VGC 2024 Term Loan”). During the year ended December 31, 2023, the Parent Company increased the borrowing under the VGC 2024 Term Loan by an additional $115 million, and transferred the full outstanding VGC 2024 Term Loan balance to VGC, its wholly-owned subsidiary, which resulted in a non-cash distribution to the Parent Company of $339 million.

Note 4 – Supplemental Cash Flow Information

The following table sets forth supplemental disclosure of cash flow information (in millions):

 

     Years ended
December 31,
 
   2023      2022      2021  

Venture Global share-based compensation incurred by subsidiary

   $ 141      $ —         —   

Paid-in-kind interest on VGC 2024 Term loan

     19        13        3  

Accrued purchases of property, plant and equipment

     2        —         —   

Cash paid for interest

     —         7        1  

Right-of-use assets in exchange for new operating lease liabilities

     —         3        —   

 

F-73


Table of Contents

 

 

   Shares

Class A common stock

Venture Global, Inc.

 

LOGO

 

 

 

PROSPECTUS

 

 

   , 2024

 

 

 


Table of Contents

PART II

INFORMATION NOT REQUIRED IN PROSPECTUS

Item 13. Other Expenses of Issuance and Distribution

 

     Amount to Be
Paid
 

SEC registration fee

   $   

FINRA filing fee

        

Listing fee

        

Transfer agent’s fees

    

Printing and engraving expenses

    

Legal fees and expenses

    

Accounting fees and expenses

    

Blue Sky fees and expenses

    

Miscellaneous

    
  

 

 

 

Total

   $   
  

 

 

 

 

*

To be completed by amendment.

Each of the amounts set forth above, other than the registration fee and the FINRA filing fee, is an estimate.

Item 14. Indemnification of Directors and Officers

Section 145 of the Delaware General Corporation Law provides that a corporation may indemnify directors and officers as well as other employees and individuals against expenses (including attorneys’ fees), judgments, fines and amounts paid in settlement actually and reasonably incurred by such person in connection with any threatened, pending or completed actions, suits or proceedings in which such person is made a party by reason of such person being or having been a director, officer, employee or agent to the registrant. The Delaware General Corporation Law provides that Section 145 is not exclusive of other rights to which those seeking indemnification may be entitled under any bylaw, agreement, vote of stockholders or disinterested directors or otherwise. Following completion of this offering, the registrant’s amended and restated certificate of incorporation and amended and restated bylaws will provide for indemnification by the registrant of its directors, officers and employees to the fullest extent permitted by the Delaware General Corporation Law. Upon completion of this offering, the registrant will enter into indemnification agreements with each of its current directors and officers to provide these directors and executive officers additional contractual assurances regarding the scope of the indemnification set forth in the registrant’s amended and restated certificate of incorporation and amended and restated bylaws and to provide additional procedural protections. There is no pending litigation or proceeding involving a director or executive officer of the registrant for which indemnification is sought.

Section 102(b)(7) of the Delaware General Corporation Law permits a corporation to provide in its certificate of incorporation that a director or officer of the corporation shall not be personally liable to the corporation or its stockholders for monetary damages for breach of fiduciary duty as a director or officer, except for liability (i) for any breach of the director’s or officer’s duty of loyalty to the corporation or its stockholders, (ii) for acts or omissions not in good faith or which involve intentional misconduct or a knowing violation of law, (iii) for a director for unlawful payments of dividends or unlawful stock repurchases, redemptions or other distributions, (iv) for any transaction from which the director or officer derived an improper personal benefit or (v) for an officer in any action by or in the right of the corporation. The registrant’s amended and restated certificate of incorporation will provide for such limitation of liability.

 

II-1


Table of Contents

The registrant maintains standard policies of insurance under which coverage is provided (a) to its directors and officers against loss rising from claims made by reason of breach of duty or other wrongful act, and (b) to the registrant with respect to payments which may be made by the registrant to such officers and directors pursuant to the above indemnification provision or otherwise as a matter of law.

The proposed form of underwriting agreement filed as Exhibit 1.1 to this registration statement provides for indemnification of directors and officers of the registrant by the underwriters against certain liabilities.

Item 15. Recent Sales of Unregistered Securities

For the past three fiscal years, the registrant has issued and sold the following securities (which does not reflect the Stock Split) without registration under the Securities Act:

(a) Issuances of Common Stock

In connection with the Reorganization Transactions, the Company issued (i) 78,464 shares of Class A common stock to certain entities affiliated with Pacific Investment Management Company then holding VGLNG’s Series C common stock, (ii) 435,500 shares of Class A common stock to VG Partners, in exchange for its equity interests in Venture Global Partners, LLC and (iii) 5,808 shares of Class A common stock to certain other holders of VGLNG’s Series C common stock, in exchange for such VGLNG’s Series C common stock.

In connection with the common stock issuances described above, we relied on the exemption from registration provided by Section 4(a)(2) of the Securities Act on the basis that the transactions did not involve a public offering.

In connection with this offering, all of the outstanding shares of Class A common stock held by VG Partners will convert into an aggregate of    shares of Class B common stock, par value $0.01 per share. The automatic conversion of such shares will not represent an offer or sale of securities under the Securities Act.

(b) Grants of Options

Prior to the Reorganization Transactions, VGLNG granted stock options to purchase shares of its Series A common stock pursuant to VGLNG’s 2014 Stock Option Plan (as amended from time to time), or the 2014 Plan, since the 2014 Plan’s adoption on December 16, 2014. In connection with the Reorganization Transactions, all such options outstanding under the 2014 Plan were automatically converted, on a one-for-one basis, in accordance with and pursuant to the terms of the 2014 Plan, into options to purchase shares of our Class A common stock, subject to the terms and conditions of the Amended and Restated Venture Global, Inc. 2023 Stock Option Plan, or the 2023 Plan. Such option grants were as follows (without giving effect to the Stock Split):

 

   

between March 8, 2021 and June 23, 2021, VGLNG granted options to purchase an aggregate of 4,050 shares of its Series A common stock, with an exercise price per share of $7,000, to certain of its current executive officers and other employees;

 

   

between August 9, 2021 and October 29, 2021, VGLNG granted options to purchase an aggregate of 1,650 shares of its Series A common stock, with an exercise price per share of $10,000, to certain of its current directors and other employees;

 

   

between January 14, 2022, and January 28, 2022, VGLNG granted options to purchase an aggregate of 1,000 shares of its Series A common stock, with an exercise price per share of $12,000, to certain of its current directors;

 

   

between May 12, 2022, and September 6, 2022, VGLNG granted options to purchase an aggregate of 8,000 shares of its Series A common stock, with an exercise price per share of $15,300, to certain of its current executive officers and other employees;

 

II-2


Table of Contents
   

between February 6, 2023, and June 1, 2023, VGLNG granted options to purchase an aggregate of 600 shares of its Series A common stock, with an exercise price per share of $18,000, to certain of its current directors and other employees;

 

   

on July 17, 2023, VGLNG granted options to purchase an aggregate of 100 shares of its Series A common stock, with an exercise price per share of $23,700, to certain of its current employees; and

 

   

on February 22, 2024, VGLNG granted options to purchase an aggregate of 100 shares of its Class A common stock, with an exercise price per share of $29,200 to certain of its current employees.

For all of the option grants described above, we relied on the exemption from registration provided by Rule 701 under the Securities Act on the basis that the 2014 Plan and the 2023 Plan are each a written compensatory benefit plan and at the time of the grants we were not subject to the reporting requirements of Section 13 or 15(d) of the Exchange Act and were not an investment company registered or required to be registered under the Investment Company Act of 1940, as amended.

All of the foregoing securities are deemed restricted securities for purposes of the Securities Act. All certificates representing the issued shares of capital stock described in this Item 15 included appropriate legends setting forth that the securities have not been registered and the applicable restrictions on transfer.

Item 16. Exhibits and Financial Statement Schedules

 

  (a)

Exhibits: The list of exhibits set forth under “Exhibit Index” at the end of this Registration Statement is incorporated herein by reference.

 

  (b)

Financial Statement Schedules. Schedule I – Condensed Financial Information of Venture Global, Inc. is included in the Registration Statement beginning on page F-69.

Item 17. Undertakings

The undersigned registrant hereby undertakes:

 

  (a)

The undersigned registrant hereby undertakes to provide to the underwriter at the closing specified in the underwriting agreement certificates in such denominations and registered in such names as required by the underwriter to permit prompt delivery to each purchaser.

 

  (b)

Insofar as indemnification for liabilities arising under the Securities Act of 1933 may be permitted to directors, officers and controlling persons of the registrant pursuant to the provisions referenced in Item 14 of this registration statement, or otherwise, the registrant has been advised that in the opinion of the Securities and Exchange Commission such indemnification is against public policy as expressed in the Act and is, therefore, unenforceable. In the event that a claim for indemnification against such liabilities (other than the payment by the registrant of expenses incurred or paid by a director, officer, or controlling person of the registrant in the successful defense of any action, suit or proceeding) is asserted by such director, officer or controlling person in connection with the securities being registered hereunder, the registrant will, unless in the opinion of its counsel the matter has been settled by controlling precedent, submit to a court of appropriate jurisdiction the question of whether such indemnification by it is against public policy as expressed in the Act and will be governed by the final adjudication of such issue.

 

  (c)

The undersigned registrant hereby undertakes that:

 

  (1)

For purposes of determining any liability under the Securities Act of 1933, the information omitted from the form of prospectus filed as part of this registration statement in reliance upon Rule 430A and contained in a form of prospectus filed by the registrant pursuant to Rule 424(b)(1) or (4) or 497(h) under the Securities Act shall be deemed to be part of this registration statement as of the time it was declared effective.

 

II-3


Table of Contents
  (2)

For the purpose of determining any liability under the Securities Act of 1933, each post-effective amendment that contains a form of prospectus shall be deemed to be a new registration statement relating to the securities offered therein, and the offering of such securities at that time shall be deemed to be the initial bona fide offering thereof.

 

II-4


Table of Contents

EXHIBIT INDEX

 

Exhibit
Number
  

Description

  1.1    Form of Underwriting Agreement
  3.1    Form of Second Amended and Restated Certificate of Incorporation (to be effective upon consummation of this offering)
  3.2    Form of Third Amended and Restated By-Laws (to be effective following consummation of this offering)
  4.1    Form of Class A Common Stock Certificate
  5.1    Form of Opinion of Davis Polk & Wardwell LLP
 10.1    Form of Amended and Restated Shareholders’ Agreement (to be effective upon consummation of this offering)
 10.2§    Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January 7, 2022, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.3    Guaranty Agreement, dated as of April  21, 2021, by KBR, Inc., for the benefit of Venture Global Plaquemines LNG, LLC, pursuant to the Amended and Restated Engineering, Procurement and Construction Agreement, dated as of April  21, 2021, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.4    Guaranty Agreement, dated as of April  21, 2021, by Zachry Holdings, Inc., for the benefit of Venture Global Plaquemines LNG, LLC, pursuant to the Amended and Restated Engineering, Procurement and Construction Agreement, dated as of April  21, 2021, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.5§    Limited Notice to Proceed No.1 (ITP), dated as of September 24, 2021, pursuant to the Amended and Restated Engineering, Procurement and Construction Agreement, dated as of April  21, 2021, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.6§    Change Order No. 1, dated as of May 17, 2022, to the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January  7, 2022, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.7§    Change Order No. 2, dated as of May 20, 2022, to the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January  7, 2022, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.8§    Change Order No. 3, dated as of September 30, 2022, to the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January  7, 2022, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.9§    Amendment No. 1 to the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of October  11, 2022, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.10§    Change Order No. 4, dated as of October 12, 2022, to the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January  7, 2022, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.11§    Amendment No. 2 to the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of February  1, 2023, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.12§    Change Order No. 5, dated as of March 2, 2023, to the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January  7, 2022, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC

 

II-5


Table of Contents
Exhibit
Number
  

Description

 10.13    Amendment No. 3 to the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of September  26, 2023, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.14§    Amendment No. 4 to the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of September  26, 2023, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.15    Amendment No. 5 to the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January  19, 2024, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.16    Amendment No. 6 to the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of July 2, 2024, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.17§    Engineering, Procurement and Construction Agreement, dated as of January 10, 2023, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.18    Guaranty Agreement, dated as of January  10, 2023, by KBR Inc., for the benefit of Venture Global Plaquemines LNG, LLC pursuant to the Engineering, Procurement and Construction Agreement, dated as of January 10, 2023, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.19    Guaranty Agreement, dated as of January  10, 2023, by Zachry Holdings, Inc., for the benefit of Venture Global Plaquemines LNG, LLC pursuant to the Engineering, Procurement and Construction Agreement, dated as of January  10, 2023, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.20§    Amendment No. 1 to the Engineering Procurement and Construction Agreement, dated as of September 26, 2023, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.21    Amendment No. 2 to the Engineering, Procurement and Construction Agreement, dated as of July 2, 2024, by and between Venture Global Plaquemines LNG, LLC and KZJV LLC
 10.22§    Engineering, Procurement and Construction Agreement, dated as of May 12, 2023, by and between Venture Global CP2 LNG, LLC and Worley Field Services, Inc.
 10.23    Guaranty Agreement, dated as of June  8, 2023, by Worley Limited, for the benefit of Venture Global CP2 LNG, LLC, pursuant to the Engineering, Procurement and Construction Agreement, dated as of May 12, 2023, by and between Venture Global CP2 LNG, LLC and Worley Field Services, Inc.
 10.24§    Change Order No. 1, dated as of November 9, 2023, to the Engineering, Procurement and Construction Agreement, dated as of May  12, 2023, by and between Venture Global CP2 LNG, LLC and Worley Field Services, Inc.
 10.25§    Change Order No. 2, dated as of November 30, 2023, to the Engineering, Procurement and Construction Agreement, dated as of May  12, 2023, by and between Venture Global CP2 LNG, LLC and Worley Field Services, Inc.
 10.26§    Change Order No. 3, dated as of February 23, 2024, to the Engineering, Procurement and Construction Agreement, dated as of May  12, 2023, by and between Venture Global CP2 LNG, LLC and Worley Field Services, Inc.
 10.27§    Change Order No. 4, dated as of March 14, 2024, to the Engineering, Procurement and Construction Agreement, dated as of May  12, 2023, by and between Venture Global CP2 LNG, LLC and Worley Field Services, Inc.
 10.28§    Change Order No. 5, dated as of April 1, 2024, to the Engineering, Procurement and Construction Agreement, dated as of May  12, 2023, by and between Venture Global CP2 LNG, LLC and Worley Field Services, Inc.

 

II-6


Table of Contents
Exhibit
Number
  

Description

 10.29    Amendment No. 1 to the Engineering, Procurement and Construction Agreement, dated as of May 10, 2024, by and between Venture Global CP2 LNG, LLC and Worley Field Services, Inc.
 10.30§    Amendment No. 2 to the Engineering, Procurement and Construction Agreement, dated as of May 22, 2024, by and between Venture Global CP2 LNG, LLC and Worley Field Services, Inc.
 10.31§    Change Order No. 6 Rev. 1, dated as of June 17, 2024, to the Engineering, Procurement and Construction Agreement, dated as of May  12, 2023, by and between Venture Global CP2 LNG, LLC and Worley Field Services, Inc.
 10.32§    Fourth Amended and Restated Letter of Agreement, dated as of April 7, 2023, by and between Venture Global LNG, Inc. and Baker Hughes Energy Services LLC
 10.33§    Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January 19, 2022, by Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC
 10.34    Guaranty Agreement, dated as of February  26, 2021, by Baker Hughes Holdings LLC, for the benefit of Venture Global Plaquemines LNG, LLC pursuant to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of February  26, 2021, by and between Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC
 10.35§    Change Order No. 2, dated as of February 25, 2022, to the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January  19, 2022, by and between Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC
 10.36§    Change Order No. 3, dated as of October 24, 2022, to the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January  19, 2022, by and between Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC
 10.37§    Change Order No. 4, dated as of April 7, 2023, to the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January  19, 2022, by and between Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC
 10.38§    Change Order No. 5, dated as of May 18, 2023, to the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January  19, 2022, by and between Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC
 10.39§    Change Order No. 6, dated as of December 29, 2023, to the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January  19, 2022, by and between Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC
 10.40§    Purchase Order Contract for the Sale of Liquefaction Train System, dated as of August 5, 2022, by and between Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC
 10.41    Guaranty Agreement, dated as of August  5, 2022, by Baker Hughes Holdings LLC, for the benefit of Venture Global Plaquemines LNG, LLC, pursuant to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of August  5, 2022, by and between Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC
 10.42§    Change Order No. 1, dated as of April 7, 2023, to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of August  5, 2022, by and between Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC
 10.43§    Change Order No. 2, dated as of May 24, 2023, to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of August  5, 2022, by and between Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC
 10.44§    Change Order No. 3, dated as of August 29, 2024, to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of August  5, 2022, by and between Baker Hughes Energy Services LLC and Venture Global Plaquemines LNG, LLC

 

II-7


Table of Contents
Exhibit
Number
  

Description

 10.45§    Purchase Order Contract for the Sale of Liquefaction Train System, dated as of April 7, 2023, by and between Baker Hughes Energy Services LLC and Venture Global CP2 LNG, LLC
 10.46§    Change Order No. 1, dated as of August 8, 2024, to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of April  7, 2023, by and between Baker Hughes Energy Services LLC and Venture Global CP2 LNG, LLC
 10.47§    Change Order No. 2, dated as of November 15, 2024, to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of April  7, 2023, by and between Baker Hughes Energy Services LLC and Venture Global CP2 LNG, LLC
 10.48    Purchase Order Contract for the Sale of Liquefaction Train System, dated as of December 13, 2024 by and between Baker Hughes Energy Services LLC and Venture Global CP2 LNG, LLC
 10.49    Guaranty Agreement, dated as of April  13, 2023, by Baker Hughes Holdings LLC, for the benefit of Venture Global CP2 LNG, LLC, pursuant to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of April  7, 2023, by and between Baker Hughes Energy Services LLC and Venture Global CP2 LNG, LLC
 10.50    Guaranty Agreement, dated as of May  4, 2023, by Venture Global LNG, Inc., for the benefit of Baker Hughes Energy Services LLC, pursuant to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of April  7, 2023, by and between Baker Hughes Energy Services LLC and Venture Global CP2 LNG, LLC
 10.51§    Amended and Restated Ground Lease Agreement, dated as of July 15, 2019, by and between Venture Global Calcasieu Pass, LLC and JADP Venture, LLC
 10.52§    First Amendment to Amended and Restated Ground Lease Agreement, dated as of December 12, 2023, by and between Venture Global Calcasieu Pass, LLC and JADP Venture, LLC
 10.53§    Amended and Restated Ground Lease Agreement, dated as of June 20, 2019, by and between Venture Global Calcasieu Pass, LLC and Henry Venture LLC
 10.54§    Ground Lease Agreement, dated as of July 19, 2021, by and between Venture Global Plaquemines LNG, LLC and the Plaquemines Port Harbor and Terminal District
 10.55§    Ground Lease Agreement, dated as of January 19, 2022, by and between Plaquemines Land Ventures, LLC, and the Plaquemines Port Harbor and Terminal District
 10.56§    Amended and Restated Ground Lease Agreement, dated as of September 19, 2023, by and between Cameron Land Ventures, LLC and J.A. Davis Properties, LLC
 10.57§    Ground Lease Agreement, dated of October 12, 2023, by and between Venture Global CP2 LNG, LLC, and Wilma Davis Bride Family, LLC
 10.58§    Ground Lease Agreement, dated as of October 12, 2023, by and between Venture Global CP2 LNG, LLC, and Ardoin Henry, LLC
 10.59§    Ground Lease Agreement, dated as of October 12, 2023, by and between Venture Global CP2 LNG, LLC and Miller Estate Leasing Company, LLC
 10.60§    Ground Lease Agreement, dated as of October 12, 2023, by and between Venture Global CP2 LNG, LLC, and Charlotte Ann LaBove and Carlotta Ann Savoie
 10.61§    Ground Lease Agreement, dated as of October 24, 2023, by and between Venture Global CP2 LNG, LLC and Cameron Parish Port, Harbor and Terminal District
 10.62§    Ground Lease Agreement, dated as of March 11, 2019, by and between Venture Global Calcasieu Pass, LLC and Henry Venture, LLC

 

II-8


Table of Contents
Exhibit
Number
  

Description

 10.63§    Ground Lease Agreement, dated as of December 12, 2023, by and between Venture Global CP2 LNG, LLC and JADP Venture, LLC
 10.64§    Limited Liability Company Agreement, dated as of August 19, 2019, among Calcasieu Pass Funding, LLC and the Members named therein
 10.65    Limited Liability Company Agreement, dated as of August 19, 2019, by and among Calcasieu Pass Holdings, LLC and the Members named therein
 10.66    Amendment No. 1 to the Limited Liability Company Agreement of Calcasieu Pass Funding, LLC, dated as of February 8, 2021
 10.67    Amendment No. 1 to the Limited Liability Company Agreement of Calcasieu Pass Holdings, LLC, dated as of February 8, 2021
 10.68    Amendment No. 2 to the Limited Liability Company Agreement of Calcasieu Pass Funding, LLC, dated as of October 27, 2021
 10.69    Amendment No. 2 to the Limited Liability Company Agreement of Calcasieu Pass Holdings, LLC, dated as of October 27, 2021
 10.70    Amendment No. 3 to the Limited Liability Company Agreement of Calcasieu Pass Funding, LLC, dated as of July 30, 2022
 10.71    Amendment No. 3 to the Limited Liability Company Agreement of Calcasieu Pass Holdings, LLC, dated as of July 30, 2022
 10.72§    Credit Facility Agreement, dated as of August 19, 2019, by and among Venture Global Calcasieu Pass, LLC, TransCameron Pipeline,  LLC, the lenders party thereto from time to time, the issuing banks thereto from time to time, Natixis, New York Branch, as credit facility agent, and Mizuho Bank (USA), as collateral agent
 10.73§    Common Terms Agreement for the Loans, dated as of August 19, 2019, by and among Venture Global Calcasieu Pass, LLC, TransCameron Pipeline, LLC, Natixis, New  York Branch, as credit facility agent, Mizuho Bank, Ltd., as intercreditor agent, and each other facility agent party thereto from time to time
 10.74    Consent and Amendment to the Common Terms Agreement and the Credit Facility Agreement, dated as of December 28, 2020, in respect of the Common Terms Agreement, dated as of August  19, 2019, and the Credit Facility Agreement, dated as of August 19, 2019
 10.75    Second Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of January 26, 2021, in respect of the Common Terms Agreement, dated as of August  19, 2019, and the Credit Facility Agreement, dated as of August 19, 2019
 10.76§    Consent and Amendment to Credit Facility Agreement, dated as of September 30, 2021, in respect of the Credit Facility Agreement, dated as of August 19, 2019
 10.77    Third Amendment to the Common Terms Agreement, First Amendment to the Common Security and Account Agreement and Consent to the Credit Facility Agreement, dated May  25, 2022, in respect of the Common Terms Agreement, dated as of August 19, 2019, the Common Security and Account Agreement, dated as of August 19, 2019, and the Credit Facility Agreement, dated as of August 19, 2019
 10.78    Fourth Amendment to the Common Terms Agreement and Second Amendment to the Credit Facility Agreement, dated as of October 12, 2022, in respect of the Common Terms Agreement, dated as of August  19, 2019, and the Credit Facility Agreement, dated as of August 19, 2019

 

II-9


Table of Contents
Exhibit
Number
  

Description

 10.79§    Fifth Amendment to the Common Terms Agreement and Third Amendment to the Common Security and Account Agreement, dated as of February  27, 2023, in respect of the Common Terms Agreement, dated as of August 19, 2019, and the Common Security and Account Agreement, dated as of August 19, 2019
 10.80    Third Amendment to the Credit Facility Agreement, dated as of May 26, 2023, in respect of the Credit Facility Agreement, dated as of August 19, 2019
 10.81    Sixth Amendment to the Common Terms Agreement and Fourth Amendment to the Common Security and Account Agreement, dated as of June  30, 2023, in respect of the Common Terms Agreement, dated as of August 19, 2019, and the Common Security and Account Agreement, dated as of August 19, 2019
 10.82§    Seventh Amendment to the Common Terms Agreement and Fifth Amendment to the Common Security and Account Agreement, dated as of October 23, 2024, in respect of the Common Terms Agreement, dated as of August 19, 2019, and the Common Security and Account Agreement, dated as of August 19, 2019
 10.83§    Indenture, dated as of August  5, 2021, by and among Venture Global Calcasieu Pass, LLC, as Issuer, TransCameron Pipeline LLC, as Guarantor, and The Bank of New York Mellon Trust Company, N.A., as Trustee, relating to the Issuer’s 3.875% Senior Secured Notes due 2029 and 4.125% Senior Secured Notes due 2031
 10.84§    First Supplemental Indenture, dated as of November  22, 2021, by and among Venture Global Calcasieu Pass, LLC, TransCameron Pipeline LLC and The Bank of New York Mellon Trust Company, N.A., to the Indenture dated as of August 5, 2021
 10.85§    Second Supplemental Indenture, dated as of January  13, 2023, by and among Venture Global Calcasieu Pass, LLC, TransCameron Pipeline LLC and The Bank of New York Mellon Trust Company, N.A., to the Indenture dated as of August 5, 2021
 10.86§    Amended and Restated Credit Facility Agreement, dated as of March  13, 2023, by and among Venture Global Plaquemines LNG, LLC, Venture Global Gator Express, LLC, the lenders party thereto from time to time, the issuing banks thereto from time to time, Natixis, New York Branch, as credit facility agent, and Royal Bank of Canada, as collateral agent
 10.87    Amended and Restated Common Terms Agreement for the Loans, dated as of March  13, 2023, by and among Venture Global Plaquemines LNG, LLC, Venture Global Gator Express, LLC, Natixis, New York Branch, as credit facility agent, and Royal Bank of Canada, as intercreditor agent
 10.88    Amendment No. 1 to the Common Terms Agreement, dated as of September 29, 2023, in respect of the Amended and Restated Common Terms Agreement, dated as of March 13, 2023
 10.89    Amendment No. 2 to the Common Terms Agreement and Amendment No. 1 to the Common Security and Account Agreement, dated as of May 15, 2024, in respect of the Amended and Restated Common Terms Agreement, dated as of March 13, 2023
 10.90§    Amendment No. 3 to the Common Terms Agreement, dated as of October 23, 2024, in respect of the Amended and Restated Common Terms Agreement, dated as of March 13, 2023
 10.91    Indenture, dated as of May  26, 2023, by and between Venture Global LNG, Inc., as Issuer, and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent, relating to the Issuer’s 8.125% Senior Secured Notes due 2028 and 8.375% Senior Secured Notes due 2031
 10.92    First Supplemental Indenture, dated as of September  25, 2023, by and between Venture Global LNG, Inc. and The Bank of New York Mellon Trust Company, N.A., relating to the Indenture dated as of May 26, 2023

 

II-10


Table of Contents
Exhibit
Number
  

Description

 10.93    Second Supplemental Indenture, dated as of September  28, 2023, by and among Venture Global Commodities, LLC, Venture Global LNG, Inc. and The Bank of New York Mellon Trust Company, N.A., relating to the Indenture dated as of May 26, 2023
 10.94§    Third Supplemental Indenture, dated as of October  24, 2023, by and among Venture Global Commodities, LLC, Venture Global LNG, Inc. and The Bank of New York Mellon Trust Company, N.A., relating to the Indenture, dated as of May 26, 2023
 10.95    Indenture, dated as of October  24, 2023, by and between Venture Global LNG, Inc., as Issuer, and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent, relating to the Issuer’s 9.500% Senior Secured Notes due 2029 and 9.875% Senior Secured Notes due 2032
 10.96§    First Supplemental Indenture, dated as of November  8, 2023, by and between Venture Global LNG, Inc. and The Bank of New York Mellon Trust Company, N.A., relating to the Indenture dated as of October 24, 2023
 10.97    Indenture, dated as of July  24, 2024, by and between Venture Global LNG, Inc., as Issuer, and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent, relating to the Issuer’s 7.00% Senior Secured Notes due 2030
 10.98    Management Services Agreement, dated as of December 1, 2014, by and between Venture Global Commodities, LLC and Venture Global Partners, LLC
 10.99    Second Amended and Restated Management Services Agreement, dated as of April 20, 2015, by and between Venture Global LNG, Inc. and Venture Global Partners, LLC
 10.100#    Venture Global LNG, Inc. 9.00% Series A Fixed-Rate Reset Cumulative Redeemable Perpetual Preferred Stock Certificate of Designations filed with the Secretary of the State of Delaware on September 30, 2024.
 10.101#    Venture Global Holdings, Inc. 2023 Stock Option Plan (as amended and restated November 14, 2024)
 10.102#    Form of Venture Global Holdings, Inc. 2023 Stock Option Plan Non-Qualified Stock Option Agreement
 10.103#*    Venture Global, Inc. Omnibus Incentive Plan
 10.104#*    Executive Employment Agreement, by and between Venture Global LNG, Inc. and Michael Sabel, dated as of  
 10.105#*    Executive Employment Agreement, by and between Venture Global LNG, Inc. and Jonathan Thayer, dated as of  
 10.106#*    Executive Employment Agreement, by and between Venture Global LNG, Inc. and Robert Pender, dated as of  
 10.107#*    Executive Amended and Restated Services Agreement, by and between Venture Global LNG, Inc. and Thomas Earl, dated as of  
 10.108#*    Executive Employment Agreement, by and between Venture Global LNG, Inc. and Keith Larson, dated as of  
 10.109#*    Executive Employment Agreement, by and between Venture Global LNG, Inc. and Brian Cothran, dated as of  
 10.110#*    Executive Employment Agreement, by and between Venture Global LNG, Inc. and Fory Musser, dated as of  
 10.111#    Form of Restrictive Covenant Agreement
 10.112#    Form of Indemnification Agreement

 

II-11


Table of Contents
Exhibit
Number
  

Description

 21.1    Subsidiaries of the registrant
 23.1    Consent of Independent Registered Public Accounting Firm
 23.2    Form of Consent of Davis Polk & Wardwell LLP (included in Exhibit 5.1)
 24.1    Power of Attorney (included on signature page)
 107    Filing Fee Exhibit

 

*

To be filed by amendment.

#

Indicates management contract or compensatory plan.

§

Portions of this exhibit have been omitted in compliance with Regulation S-K, Item 601(a)(6) and/or Item 601(b)(10)(iv).

 

II-12


Table of Contents

SIGNATURES

Pursuant to the requirements of the Securities Act of 1933, the registrant has duly caused this registration statement to be signed on its behalf by the undersigned, thereunto duly authorized, in the City of Arlington, Virginia, on the 20th day of December, 2024.

 

VENTURE GLOBAL, INC.
By:  

/s/ Michael Sabel

 

Name:Michael Sabel

 

Title:   Chief Executive Officer

KNOW ALL PERSONS BY THESE PRESENTS, that each person whose signature appears below constitutes and appoints Jonathan Thayer and Keith Larson, and each of them, his or her true and lawful attorneys-in-fact and agents, with full power of substitution and resubstitution, for him or her and in his or her name, place and stead, in any and all capacities, to sign any and all amendments (including post-effective amendments) to this registration statement and any and all additional registration statements pursuant to Rule 462(b) of the Securities Act of 1933, and to file the same, with all exhibits thereto, and all other documents in connection therewith, with the Securities and Exchange Commission, granting unto each said attorney-in-fact and agents full power and authority to do and perform each and every act in person, hereby ratifying and confirming all that said attorneys-in-fact and agents or either of them or their or his or her substitute or substitutes may lawfully do or cause to be done by virtue hereof.

Pursuant to the requirements of the Securities Act of 1933, this registration statement has been signed by the following persons in the capacities and on the dates indicated.

 

Signature

  

Title

 

Date

/s/ Michael Sabel

Michael Sabel

  

Chief Executive Officer, Director, Executive Co-Chairman of the Board and Founder
(Principal Executive Officer)

  December 20, 2024

/s/ Robert Pender

Robert Pender

  

Executive Co-Chairman, Director, Executive Co-Chairman of the Board, and Founder

  December 20, 2024

/s/ Jonathan Thayer

Jonathan Thayer

  

Chief Financial Officer
(Principal Financial Officer)

  December 20, 2024

/s/ Sarah Blake

Sarah Blake

  

Chief Accounting Officer
(Principal Accounting Officer)

  December 20, 2024

/s/ Sari Granat

Sari Granat

  

Director

  December 20, 2024

/s/ Andrew Orekar

Andrew Orekar

  

Director

  December 20, 2024

/s/ Thomas J. Reid

Thomas J. Reid

  

Director

  December 20, 2024

/s/ Jimmy Staton

Jimmy Staton

  

Director

  December 20, 2024

/s/ Roderick Christie

Roderick Christie

  

Director

  December 20, 2024

 

II-13

Exhibit 1.1

Venture Global, Inc.

[●] Shares of Class A Common Stock

Underwriting Agreement

[●], 2025

Goldman Sachs & Co. LLC

J.P. Morgan Securities LLC

BofA Securities, Inc.

As Representatives of the

 several Underwriters listed

 in Schedule 1 hereto

c/o Goldman Sachs & Co. LLC

200 West Street

New York, NY 10282-2198

c/o J.P. Morgan Securities LLC

383 Madison Avenue

New York, New York 10179

c/o BofA Securities, Inc.

One Bryant Park

New York, New York 10036

Ladies and Gentlemen:

Venture Global, Inc., a Delaware corporation (the “Company”), proposes to issue and sell to the several underwriters listed in Schedule 1 hereto (the “Underwriters”), for whom you are acting as representatives (the “Representatives”), an aggregate of [•] shares of Class A Common Stock, par value $0.01 per share (“Class A Common Stock”), of the Company (the “Underwritten Shares”) and, at the option of the Underwriters, up to an additional [●] shares of Class A Common Stock (the “Option Shares”). The Underwritten Shares and the Option Shares are herein referred to as the “Shares”. The shares of Class A Common Stock to be outstanding after giving effect to the sale of the Shares are referred to herein as the “Stock”.


The Company hereby confirms its agreement with the several Underwriters concerning the purchase and sale of the Shares, as follows:

1. Registration Statement. The Company has prepared and filed with the Securities and Exchange Commission (the “Commission”) under the Securities Act of 1933, as amended, and the rules and regulations of the Commission thereunder (collectively, the “Securities Act”), a registration statement (File No. 333-[●]), including a prospectus, relating to the Shares. Such registration statement, as amended at the time it became effective, including the information, if any, deemed pursuant to Rule 430A, 430B or 430C under the Securities Act to be part of the registration statement at the time of its effectiveness (“Rule 430 Information”), is referred to herein as the “Registration Statement”; and as used herein, the term “Preliminary Prospectus” means each prospectus included in such registration statement (and any amendments thereto) before effectiveness, any prospectus filed with the Commission pursuant to Rule 424(a) under the Securities Act and the prospectus included in the Registration Statement at the time of its effectiveness that omits Rule 430 Information, and the term “Prospectus” means the prospectus in the form first used (or made available upon request of purchasers pursuant to Rule 173 under the Securities Act) in connection with confirmation of sales of the Shares. If the Company has filed an abbreviated registration statement pursuant to Rule 462(b) under the Securities Act (the “Rule 462 Registration Statement”), then any reference herein to the term “Registration Statement” shall be deemed to include such Rule 462 Registration Statement. Capitalized terms used but not defined herein shall have the meanings given to such terms in the Registration Statement and the Prospectus.

At or prior to the Applicable Time (as defined below), the Company had prepared the following information (collectively with the pricing information set forth on Annex A, the “Pricing Disclosure Package”): a Preliminary Prospectus dated [●], 2025 and each “free-writing prospectus” (as defined pursuant to Rule 405 under the Securities Act) listed on Annex A hereto.

“Applicable Time” means [●], New York City time, on [●], 2025.

2. Purchase of the Shares.

(a) The Company agrees to issue and sell the Underwritten Shares to the several Underwriters as provided in this underwriting agreement (this “Agreement”), and each Underwriter, on the basis of the representations, warranties and agreements set forth herein and subject to the conditions set forth herein, agrees, severally and not jointly, to purchase at a price per share of $[•] (the “Purchase Price”) from the Company the respective number of Underwritten Shares set forth opposite such Underwriter’s name in Schedule 1 hereto.

In addition, the Company agrees to issue and sell the Option Shares to the several Underwriters as provided in this Agreement, and the Underwriters, on the basis of the representations, warranties and agreements set forth herein and subject to the conditions set forth herein, shall have the option to purchase, severally and not jointly, from the Company the Option Shares at the Purchase Price less an amount per share equal to any dividends or distributions declared by the Company and payable on the Underwritten Shares but not payable on the Option Shares.

If any Option Shares are to be purchased, the number of Option Shares to be purchased by each Underwriter shall be the number of Option Shares which bears the same ratio to the aggregate number of Option Shares being purchased as the number of Underwritten Shares set forth opposite the name of such Underwriter in Schedule 1 hereto (or such number increased as set forth in Section 10 hereof) bears to the aggregate number of Underwritten Shares being purchased from the Company by the several Underwriters, subject, however, to such adjustments to eliminate any fractional Shares as the Representatives in their sole discretion shall make.

 

2


The Underwriters may exercise the option to purchase Option Shares at any time in whole, or from time to time in part, on or before the thirtieth day following the date of the Prospectus, by written notice from the Representatives to the Company. Such notice shall set forth the aggregate number of Option Shares as to which the option is being exercised and the date and time when the Option Shares are to be delivered and paid for, which may be the same date and time as the Closing Date (as hereinafter defined) but shall not be earlier than the Closing Date nor later than the tenth full business day (as hereinafter defined) after the date of such notice (unless such time and date are postponed in accordance with the provisions of Section 10 hereof). Any such notice shall be given at least two business days prior to the date and time of delivery specified therein.

(b) The Company understands that the Underwriters intend to make a public offering of the Shares, and initially to offer the Shares on the terms set forth in the Pricing Disclosure Package. The Company acknowledges and agrees that the Underwriters may offer and sell Shares to or through any affiliate of an Underwriter.

(c) Payment for the Shares shall be made by wire transfer in immediately available funds to the account specified by the Company to the Representatives in the case of the Underwritten Shares, at the offices of Skadden, Arps, Slate, Meagher & Flom LLP, One Manhattan West, New York, New York 10001 at [●] New York City time on [●], 2025, or at such other time or place on the same or such other date, not later than the fifth business day thereafter, as the Representatives and the Company may agree upon in writing or, in the case of the Option Shares, on the date and at the time and place specified by the Representatives in the written notice of the Underwriters’ election to purchase such Option Shares. The time and date of such payment for the Underwritten Shares is referred to herein as the “Closing Date”, and the time and date for such payment for the Option Shares, if other than the Closing Date, is herein referred to as the “Additional Closing Date”.

Payment for the Shares to be purchased on the Closing Date or the Additional Closing Date, as the case may be, shall be made against delivery to the Representatives for the respective accounts of the several Underwriters of the Shares to be purchased on such date or the Additional Closing Date, as the case may be, with any transfer taxes payable in connection with the sale of such Shares duly paid by the Company. Delivery of the Shares shall be made through the facilities of The Depository Trust Company (“DTC”) unless the Representatives shall otherwise instruct.

(d) The Company acknowledges and agrees that the Representatives and the other Underwriters are acting solely in the capacity of an arm’s length contractual counterparty to the Company with respect to the offering of Shares contemplated hereby (including in connection with determining the terms of the offering) and not as a financial advisor or a fiduciary to, or an agent of, the Company or any other person. Additionally, neither the Representatives nor any other Underwriter is advising the Company or any other person as to any legal, tax, investment, accounting or regulatory matters in any jurisdiction. The Company shall consult with its own advisors concerning such matters and shall be responsible for making its own independent

 

3


investigation and appraisal of the transactions contemplated hereby, and neither the Representatives nor the other Underwriters shall have any responsibility or liability to the Company with respect thereto. Any review by the Representatives and the other Underwriters of the Company, the transactions contemplated hereby or other matters relating to such transactions will be performed solely for the benefit of the Underwriters and shall not be on behalf of the Company.

3. Representations and Warranties of the Company. The Company represents and warrants to each Underwriter that:

(a) Preliminary Prospectus. No order preventing or suspending the use of any Preliminary Prospectus has been issued by the Commission, and each Preliminary Prospectus included in the Pricing Disclosure Package, at the time of filing thereof, complied in all material respects with the Securities Act, and no Preliminary Prospectus, at the time of filing thereof, contained any untrue statement of a material fact or omitted to state a material fact necessary in order to make the statements therein, in the light of the circumstances under which they were made, not misleading; provided that the Company makes no representation or warranty with respect to any statements or omissions made in reliance upon and in conformity with information relating to any Underwriter furnished to the Company in writing by such Underwriter through the Representatives expressly for use in any Preliminary Prospectus, it being understood and agreed that the only such information furnished by any Underwriter consists of the information described as such in Section 7(b) hereof.

(b) Pricing Disclosure Package. The Pricing Disclosure Package as of the Applicable Time did not, and as of the Closing Date and as of the Additional Closing Date, as the case may be, will not, contain any untrue statement of a material fact or omit to state a material fact necessary in order to make the statements therein, in the light of the circumstances under which they were made, not misleading; provided that the Company makes no representation or warranty with respect to any statements or omissions made in reliance upon and in conformity with information relating to any Underwriter furnished to the Company in writing by such Underwriter through the Representatives expressly for use in such Pricing Disclosure Package, it being understood and agreed that the only such information furnished by any Underwriter consists of the information described as such in Section 7(b) hereof. No statement of material fact included in the Prospectus has been omitted from the Pricing Disclosure Package and no statement of material fact included in the Pricing Disclosure Package that is required to be included in the Prospectus has been omitted therefrom.

(c) Issuer Free Writing Prospectus. Other than the Registration Statement, the Preliminary Prospectus and the Prospectus, the Company (including its agents and representatives, other than the Underwriters in their capacity as such) has not prepared, made, used, authorized, approved or referred to and will not prepare, make, use, authorize, approve or refer to any “written communication” (as defined in Rule 405 under the Securities Act) that constitutes an offer to sell or solicitation of an offer to buy the Shares (each such communication by the Company or its agents and representatives

 

4


(other than a communication referred to in clause (i) below) an “Issuer Free Writing Prospectus”) other than (i) any document not constituting a prospectus pursuant to Section 2(a)(10)(a) of the Securities Act or Rule 134 under the Securities Act or any written communication with potential investors undertaken in reliance on Rule 163B under, the Securities Act (together with any oral communication undertaken in reliance thereon, “Testing-the-Waters Communications”), or (ii) the documents listed on Annex A hereto, each electronic road show and any other written communications approved in writing in advance by the Representatives. Each such Issuer Free Writing Prospectus complies in all material respects with the Securities Act, has been or will be (within the time period specified in Rule 433) filed in accordance with the Securities Act (to the extent required thereby) and does not conflict with the information contained in the Registration Statement or the Pricing Disclosure Package, and, when taken together with the Preliminary Prospectus accompanying, or delivered prior to delivery of, such Issuer Free Writing Prospectus, did not, and as of the Closing Date and as of the Additional Closing Date, as the case may be, will not, contain any untrue statement of a material fact or omit to state a material fact necessary in order to make the statements therein, in the light of the circumstances under which they were made, not misleading; provided that the Company makes no representation or warranty with respect to any statements or omissions made in each such Issuer Free Writing Prospectus or Preliminary Prospectus in reliance upon and in conformity with information relating to any Underwriter furnished to the Company in writing by such Underwriter through the Representatives expressly for use in such Issuer Free Writing Prospectus or Preliminary Prospectus, it being understood and agreed that the only such information furnished by any Underwriter consists of the information described as such in Section 7(b) hereof.

(d) Testing-the-Waters Materials. The Company (i) has not alone engaged in any Testing-the-Waters Communications other than Testing-the-Waters Communications with the consent of the Representatives with entities that are reasonably believed to be qualified institutional buyers (“QIBs”) within the meaning of Rule 144A under the Securities Act or institutions that are accredited investors within the meaning of Rule 501(a)(1), (a)(2), (a)(3), (a)(7) or (a)(8) under the Securities Act (“IAIs”) and otherwise in compliance with the requirements of Rule 163B under the Securities Act and (ii) has not authorized anyone other than the Representatives to engage in Testing-the-Waters Communications. The Company reconfirms that the Representatives have been authorized to act on its behalf in undertaking Testing-the-Waters Communications by virtue of a writing substantially in the form of Exhibit A hereto. The Company has not distributed or approved for distribution any Written Testing-the-Waters Communications other than those listed on Annex B hereto. “Written Testing-the-Waters Communication” means any Testing-the-Waters Communication that is a written communication within the meaning of Rule 405 under the Securities Act. Any individual Written Testing-the-Waters Communication does not conflict with the information contained in the Registration Statement or the Pricing Disclosure Package, complied in all material respects with the Securities Act, and when taken together with the Pricing Disclosure Package as of the Applicable Time, did not, and as of the Closing Date and as of the Additional Closing Date, as the case may be, will not, contain any untrue statement of a material fact or omit to state a material fact necessary in order to make the statements

 

5


therein, in the light of the circumstances under which they were made, not misleading, except insofar as such statements or facts are based upon any such untrue statement or omission or alleged untrue statement or omission made in reliance upon and in conformity with information relating to any Underwriter furnished to the Company in writing by such Underwriter through the Representatives expressly for use in any Written Testing-the-Waters Communication, the Registration Statement or the Pricing Disclosure Package, it being understood and agreed that the only such information furnished by any Underwriter consists of the information described as such in Section 7(b) hereof.

(e) Registration Statement and Prospectus. The Registration Statement has been declared effective by the Commission. No order suspending the effectiveness of the Registration Statement has been issued by the Commission, and no proceeding for that purpose or pursuant to Section 8A of the Securities Act against the Company or related to the offering of the Shares has been initiated or, to the knowledge of the Company, threatened by the Commission; as of the effective date of the Registration Statement, the Registration Statement complied and, as of the applicable effective date of each, if any, post-effective amendment thereto, such post-effective amendment will comply, in all material respects with the Securities Act, and the Registration Statement, as of the effective date thereof, did not, and such post-effective amendment, as of the effective date thereof, will not, contain any untrue statement of a material fact or omit to state a material fact required to be stated therein or necessary in order to make the statements therein not misleading; and as of the date of the Prospectus and any amendment or supplement thereto and as of the Closing Date and as of the Additional Closing Date, as the case may be, the Prospectus (as so amended or supplemented, if applicable) will comply in all material respects with the Securities Act and will not contain any untrue statement of a material fact or omit to state a material fact necessary in order to make the statements therein, in the light of the circumstances under which they were made, not misleading; provided that the Company makes no representation or warranty with respect to any statements or omissions made in reliance upon and in conformity with information relating to any Underwriter furnished to the Company in writing by such Underwriter through the Representatives expressly for use in the Registration Statement and the Prospectus and any amendment or supplement thereto, it being understood and agreed that the only such information furnished by any Underwriter consists of the information described as such in Section 7(b) hereof.

(f) Financial Statements. The financial statements (including the related notes thereto) of the Company and its consolidated subsidiaries included in the Registration Statement, the Pricing Disclosure Package and the Prospectus comply in all material respects with the applicable requirements of the Securities Act and present fairly in all material respects the financial position of the Company and its consolidated subsidiaries as of the dates indicated and the results of their operations and the changes in their cash flows for the periods specified; such financial statements have been prepared in conformity with generally accepted accounting principles (“GAAP”) in the United States applied on a consistent basis throughout the periods covered thereby, and any supporting schedules included in the Registration Statement present fairly in all material respects the information required to be stated therein; and the other financial information included in the Registration Statement, the Pricing Disclosure Package and the Prospectus has been derived from the accounting records of the Company and its consolidated subsidiaries and presents fairly in all material respects the information shown thereby.

 

6


(g) No Material Adverse Change. Since the date of the most recent financial statements of the Company included in the Registration Statement, the Pricing Disclosure Package and the Prospectus, (i) there has not been any material change in the capital stock, limited liability company, limited partnership or private limited company interest of the Company or its subsidiaries, or any distribution of any kind declared, set aside for payment, paid or made by the Company or any material distribution of any kind declared, set aside for payment, paid or made by any of the Company’s subsidiaries on any capital stock, limited liability company, limited partnership or private limited company interest, or any material adverse change, or any development involving a prospective material adverse change, in or affecting the financial condition, business, properties or results of operations of the Company, taken together with its subsidiaries; (ii) the Company and its subsidiaries have not entered into any transaction or agreement that is material to the Company, taken together with its subsidiaries, or incurred any liability or obligation, direct or contingent, that is material to the Company, taken together with its subsidiaries; and (iii) the Company, taken together with its subsidiaries, has not sustained any material loss or interference with its business from fire, explosion, flood or other calamity, whether or not covered by insurance, or from any labor disturbance or dispute or any action, order or decree of any court or arbitrator or governmental or regulatory authority, except in the case of each of clauses (i), (ii) and (iii) as otherwise disclosed in or contemplated by the Registration Statement, the Pricing Disclosure Package and the Prospectus.

(h) Company Organization and Good Standing. The Company has been duly incorporated and is validly existing as a corporation in good standing under the laws of the State of Delaware, with corporate power and authority to own or lease its properties and conduct its business as described in the Registration Statement, the Pricing Disclosure Package and the Prospectus. The Company is duly qualified to do business as a foreign corporation in good standing in all other jurisdictions (to the extent the concept of good standing is applicable in any such jurisdiction) in which its ownership or lease of property or the conduct of its business requires such qualification, except where the failure to be so qualified or have such power or authority would not, individually or in the aggregate, reasonably be expected to result in a material adverse effect on the financial condition, business, properties or results of operations of the Company and its subsidiaries, taken as a whole (a “Material Adverse Effect”). The Company has the corporate power and authority to execute and deliver, and to perform its obligations under this Agreement.

(i) Significant Subsidiaries’ Organization and Good Standing. Each subsidiary of the Company listed on Exhibit 21.1 of the Registration Statement (collectively, the “Significant Subsidiaries”) has been duly incorporated or formed, is validly existing as a corporation or a limited liability company, limited partnership or private limited company, as applicable, in good standing under the laws of the

 

7


jurisdiction of its incorporation or formation, as applicable, has the corporate, limited liability company, limited partnership or private limited company power, as applicable, and authority to own or lease its properties and conduct its business as described in the Registration Statement, the Pricing Disclosure Package and the Prospectus, except as would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect. Each Significant Subsidiary is duly qualified to do business and is in good standing in each jurisdiction (to the extent the concept of good standing is applicable in such jurisdiction) in which its ownership or lease of property or the conduct of its business requires such qualification, except where the failure to be so qualified or have such power or authority would not, individually or in the aggregate, reasonably be expected to result in a Material Adverse Effect; all of the issued corporate, limited liability company, limited partnership and private limited company interests of each Significant Subsidiary, as applicable, have been duly and validly authorized and issued, are fully paid (to the extent required under any applicable partnership agreement) and non-assessable (except as such nonassessability may be affected by Sections 17-607 and 17-804 of the Delaware Revised Uniform Limited Partnership Act (the “DRULPA”), with respect to limited partnership interests, and as otherwise described in the Registration Statement, the Pricing Disclosure Package and the Prospectus) and are owned directly or indirectly by the Company, free and clear of all liens, encumbrances, equities or claims (other than those that are permitted under the existing indebtedness of the Company and its subsidiaries described under the “Description of Material Financing” section of the Registration Statement, the Pricing Disclosure Package and the Prospectus), except as would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect. The Company has no “significant subsidiaries” (as defined in Rule 1-02 of Regulation S-X under the Exchange Act) that are not listed in Exhibit 21.1 of the Registration Statement.

(j) Capitalization. The Company has an authorized capitalization as set forth in the Registration Statement, the Pricing Disclosure Package and the Prospectus under the headings “Capitalization” and “Description of Capital Stock”; all the outstanding shares of capital stock of the Company have been duly and validly authorized and issued and are fully paid and non-assessable and are not subject to any pre-emptive or similar rights; except as disclosed in or expressly contemplated by the Registration Statement, the Pricing Disclosure Package and the Prospectus, there are no outstanding rights (including, without limitation, pre-emptive rights), warrants or options to acquire, or instruments convertible into or exchangeable for, any shares of capital stock or other equity interest in the Company or any of its subsidiaries, or any contract, commitment, agreement, understanding or arrangement of any kind relating to the issuance of any capital stock of the Company or any such subsidiary, any such convertible or exchangeable securities or any such rights, warrants or options; the capital stock of the Company conforms in all material respects to the description thereof contained in the Registration Statement, the Pricing Disclosure Package and the Prospectus.

 

8


(k) Stock Options. With respect to the stock options (the “Stock Options”) granted pursuant to the stock-based compensation plans of the Company and its subsidiaries (the “Company Stock Plans”), (i) each Stock Option intended to qualify as an “incentive stock option” under Section 422 of the Internal Revenue Code of 1986, as amended, including the regulations and published interpretations thereunder (the “Code”), so qualifies, (ii) each grant of a Stock Option was duly authorized no later than the date on which the grant of such Stock Option was by its terms to be effective (the “Grant Date”) by all necessary corporate action, including, as applicable, approval by the board of directors of the Company (or a duly constituted and authorized committee thereof) and any required stockholder approval by the necessary number of votes or written consents, and the award agreement governing such grant (if any) was duly executed and delivered by each party thereto, (iii) each such grant was made in accordance with the terms of the Company Stock Plans, the Exchange Act and all other applicable laws and regulatory rules or requirements, including the rules of the New York Stock Exchange (the “Exchange”) and any other exchange on which Company securities are traded, and (iv) each such grant was properly accounted for in accordance with GAAP in the financial statements (including the related notes) of the Company. The Company has not knowingly granted, and there is no and has been no policy or practice of the Company of granting, Stock Options prior to, or otherwise coordinating the grant of Stock Options with, the release or other public announcement of material information regarding the Company or its subsidiaries or their results of operations or prospects.

(l) Underwriting Agreement. This Agreement has been duly authorized, executed and delivered by the Company.

(m) The Shares. The Shares to be issued and sold by the Company hereunder have been duly authorized by the Company and, when issued and delivered and paid for as provided herein, will be duly and validly issued, will be fully paid and nonassessable and will conform in all material respects to the descriptions thereof in the Registration Statement, the Pricing Disclosure Package and the Prospectus; and the issuance of the Shares is not subject to any preemptive or similar rights.

(n) Descriptions of the Underwriting Agreement. This Agreement conforms in all material respects to the description thereof contained in the Registration Statement, the Pricing Disclosure Package and the Prospectus.

(o) No Violation or Default. Except as disclosed in or contemplated by the Registration Statement, the Pricing Disclosure Package and the Prospectus, the Company and its Significant Subsidiaries are not (i) in violation of their respective charter or by-laws or similar organizational documents; (ii) in default, and no event has occurred that, with notice or lapse of time or both, would constitute such a default, in the due performance or observance of any term, covenant or condition contained in any indenture, mortgage, deed of trust, loan agreement or other agreement or instrument to which the Company or its Significant Subsidiaries are a party or by which the Company or its Significant Subsidiaries are bound or to which any of the property or assets of the Company or its Significant Subsidiaries are subject; or (iii) in violation of any law or statute applicable to the Company or its Significant Subsidiaries, or any judgment, order, rule or regulation of any court, arbitrator or governmental or regulatory authority having jurisdiction over the Company or its Significant Subsidiaries or any of their respective properties, except, in the case of clauses (ii) and (iii) above, for any such default or violation that would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect.

 

9


(p) No Conflicts. The execution, delivery and performance of this Agreement and the issuance and sale of the Shares and the consummation of the transactions contemplated by this Agreement or the Pricing Disclosure Package and the Prospectus will not result in (i) a violation of any statute, rule, regulation or order of any governmental agency or body or any court, domestic or foreign, having jurisdiction over the Company or any of its subsidiaries or any of their properties, (ii) a breach or violation of any of the terms or provisions of, or constitute a default under, any agreement or instrument to which the Company or any of its subsidiaries is a party or by which the Company or any of its subsidiaries is bound or to which any of the properties or assets of the Company or any of its subsidiaries is subject, which breach or violation has not been waived, or (iii) any violation of the provisions of the certificate of incorporation or bylaws of the Company, except, in the case of clauses (i) and (ii) above, for any such conflict, breach or violation that would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect.

(q) No Consents Required. No consent, approval, authorization, or order of, or registration or filing with, any governmental agency or body or any court is required for the Company’s execution, delivery and performance of any of this Agreement, the issuance and sale of the Shares and the consummation of the transactions contemplated by this Agreement, except (i) the registration of the Shares under the Securities Act and such consents, approvals, authorizations, orders and registrations or qualifications as may be required by the Financial Industry Regulatory Authority, Inc. (“FINRA”) and such as have been obtained or waived or may be required under applicable state securities or Blue Sky laws in connection with the purchase and resale of the Shares by the Underwriters, and (ii) those that, if not obtained or made, would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect.

(r) Legal Proceedings. Except as described in the Registration Statement, the Pricing Disclosure Package and the Prospectus, there is no (i) action, suit or proceeding before or by any court, arbitrator or governmental agency, body or official, domestic or foreign, now pending or, to the knowledge of the Company, threatened, to which the Company or its subsidiaries may be a party or to which their business or property is or may be subject, (ii) statute, rule, regulation or order that has been enacted, adopted or issued by any governmental agency with respect to the Company or its subsidiaries or (iii) injunction, restraining order or order of any nature issued by a federal or state court or foreign court of competent jurisdiction, to which the Company or its subsidiaries are or may be subject, that, in the case of clauses (i), (ii) and (iii) above, would, individually or in the aggregate, (A) reasonably be expected to have a Material Adverse Effect, (B) prevent or result in the suspension of or otherwise adversely affect the consummation of the offering of the Shares or (C) in any manner draw into question the validity of this Agreement or the Shares; and (i) there are no current or pending legal, governmental or regulatory investigations, actions, demands, claims, suits, arbitrations, inquiries or

 

10


proceedings that are required under the Securities Act to be described in the Registration Statement, the Pricing Disclosure Package or the Prospectus that are not so described in the Registration Statement, the Pricing Disclosure Package and the Prospectus and (ii) there are no statutes, regulations or contracts or other documents that are required under the Securities Act to be filed as exhibits to the Registration Statement or described in the Registration Statement, the Pricing Disclosure Package or the Prospectus that are not so filed as exhibits to the Registration Statement or described in the Registration Statement, the Pricing Disclosure Package and the Prospectus.

(s) Independent Accountants. Ernst & Young LLP, who have certified certain financial statements of the Company and its subsidiaries, is an independent registered public accounting firm with respect to the Company and its subsidiaries within the applicable rules and regulations adopted by the Commission and the Public Company Accounting Oversight Board (United States) and as required by the Securities Act.

(t) Title to Real and Personal Property. Each of the Company and its subsidiaries has good, legal and valid interest in all real property and good and valid title to all personal property (other than with respect to Intellectual Property (as defined below), which is addressed exclusively in subsection (u) below) owned by them, in each case free and clear of all liens, encumbrances, claims and defects and imperfections of title other than such (i) that are permitted under the existing indebtedness documents described under the “Description of Material Financing” section of the Registration Statement, the Pricing Disclosure Package and the Prospectus or as are described in the Registration Statement, the Pricing Disclosure Package and the Prospectus, (ii) as do not interfere with the use made and proposed to be made of such property by the Company or any of its subsidiaries, or (iii) as would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect.

(u) Intellectual Property. Except as would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect, (i) the Company and its subsidiaries own or possess, or can acquire on reasonable terms, adequate patents, patent rights, licenses, inventions, copyrights, know how (including trade secrets and other unpatented or unpatentable proprietary or confidential information, systems or procedures), trademarks, service marks, trade names or other intellectual property (collectively, “Intellectual Property”) used in, held for use in or reasonably necessary to the conduct of the business of the Company and its subsidiaries and (ii) the Company and its subsidiaries have not received any written notice and are not otherwise aware of any infringement of or conflict with asserted rights of others with respect to any Intellectual Property or of any facts or circumstances that would reasonably be expected to render any Intellectual Property owned by the Company and its subsidiaries invalid or inadequate to protect the interests in the Company and its subsidiaries.

(v) No Undisclosed Relationships. No relationship, direct or indirect, exists between or among the Company or any of its subsidiaries, on the one hand, and the directors, officers, stockholders, customers, suppliers or other affiliates of the Company or any of its subsidiaries, on the other, that is required by the Securities Act to be described in each of the Registration Statement and the Prospectus and that is not so described in such documents and in the Pricing Disclosure Package.

 

11


(w) Investment Company Act. The Company is not an open-end investment company, unit investment trust or face-amount certificate company that is or is required to be registered under Section 8 of the United States Investment Company Act of 1940, as amended (the “Investment Company Act”); and the Company is not and, after giving effect to the offering and sale of the Shares and the application of the proceeds thereof as described in the Registration Statement, the Pricing Disclosure Package and the Prospectus, will not be, an “investment company” as defined in the Investment Company Act.

(x) Taxes. Except as would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect or that is contested in good faith by appropriate proceedings and for which adequate reserves have been established in accordance with GAAP, the Company and its subsidiaries have paid all federal, state, local and foreign taxes and filed all tax returns required to be paid or filed through the date hereof; and except as otherwise disclosed in each of the Registration Statement, the Pricing Disclosure Package and the Prospectus or as would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect, there is no tax deficiency that has been, or could reasonably be expected to be, asserted against the Company or its subsidiaries or any of their respective properties or assets.

(y) Licenses and Permits. Except as disclosed in or contemplated by the Registration Statement, the Pricing Disclosure Package and the Prospectus, the Company and its subsidiaries possess all permits, licenses, approvals, consents and other authorizations issued by the appropriate federal, state, local or foreign regulatory agencies or bodies (collectively, “Governmental Licenses”) necessary to conduct the business associated with their assets in their current stage of development, except where the failure to so possess would not, individually or in the aggregate, reasonably be expected to result in a Material Adverse Effect; the Company and its subsidiaries are in compliance with the terms and conditions of all such Governmental Licenses, except where the failure to so comply would not, individually or in the aggregate, reasonably be expected to result in a Material Adverse Effect; all of the Governmental Licenses are valid and in full force and effect, except where the invalidity of such Governmental Licenses or the failure of such Governmental Licenses to be in full force and effect would not, individually or in the aggregate, reasonably be expected to result in a Material Adverse Effect, and neither the Company nor any of its subsidiaries has received any notice of proceedings relating to the revocation or modification of any Governmental Licenses currently held by them that, if determined adversely to the Company or any of its subsidiaries, as applicable, would individually or in the aggregate reasonably be expected to have a Material Adverse Effect.

(z) No Labor Disputes. Except as would not reasonably be expected to have a Material Adverse Effect, no labor dispute with the employees of the Company or its subsidiaries exists or, to the knowledge of the Company, is imminent.

 

12


(aa) Certain Environmental Matters. Except as disclosed in or contemplated by the Registration Statement, the Pricing Disclosure Package and the Prospectus, the Company and its subsidiaries (i) are in compliance with any and all applicable federal, state and local laws and regulations relating to the prevention of pollution, the protection of the environment or human health or safety relating to Hazardous Materials (as defined below), or imposing liability or standards of conduct concerning any Hazardous Materials (“Environmental Laws”) and have been in compliance with such Environmental Laws within any applicable statute of limitation period, (ii) have received all permits, licenses, approvals or other authorizations required of them under applicable Environmental Laws (“Environmental Permits”) to conduct their business as presently conducted, (iii) are in compliance with all terms and conditions of any such Environmental Permits, (iv) do not have any liability in connection with the Release (as defined below) into the environment of any Hazardous Material, (v) have not received any written communication from a governmental authority that alleges that they are in violation of, or liable under, any Environmental Laws, (vi) have not received any written communication from any other third party that alleges that they are in violation of, or liable under, any Environmental Laws, (vii) have not received written notice from any governmental authority that they are subject to any investigation with respect to any potential violation of or liability under or pursuant to Environmental Laws, (viii) are not subject to any order, judgment, or decree with respect to liability pursuant to Environmental Laws or in connection with Hazardous Materials, except in the case of each of clauses (i) through (viii) as would not, individually or in the aggregate, have a Material Adverse Effect. The term “Hazardous Material” means (A) any “hazardous substance” as defined in the Comprehensive Environmental Response, Compensation and Liability Act of 1980, as amended, (B) any “hazardous waste” as defined in the Resource Conservation and Recovery Act, as amended, (C) any petroleum or petroleum product, (D) any polychlorinated biphenyl, (E) any per-and polyfluoroalkyl substances and (F) any pollutant or contaminant or hazardous, dangerous or toxic chemical, material, waste or substance regulated under or within the meaning of any applicable Environmental Law or which can give rise to liability under any Environmental Laws. The term “Release” means any release, spill, emission, discharge, deposit, disposal, leaking, pumping, pouring, dumping, emptying, injection or leaching into the environment.

(bb) Compliance with ERISA. Except as would not reasonably be expected to have a Material Adverse Effect, none of the Company or any of its subsidiaries sponsor or participate in, or have any obligations to contribute to, or any liability under (including any liability resulting from affiliation with any ERISA Affiliate (as defined below)), any “employee benefit plan” as defined in Section 3(3) of the Employee Retirement Income Security Act of 1974, as amended, including the regulations and published interpretations thereunder (“ERISA”), including any “multiemployer plan” as defined in Section 3(37) of ERISA. “ERISA Affiliate” means, with respect to the Company and its subsidiaries, any entity that is under common control with, or would be regarded as a single employer with, the Company under Sections 4001(a)(14) of ERISA and/or Sections 414(b), (c), (m) or (o) of the Code.

 

13


(cc) Disclosure Controls. The Company and its subsidiaries maintain an effective system of “disclosure controls and procedures” (as defined in Rule 13a-15(e) of the Exchange Act) that complies with the applicable requirements of the Exchange Act and that has been designed to ensure that information required to be disclosed by the Company in reports that it files or submits under the Exchange Act is recorded, processed, summarized and reported within the time periods specified in the Commission’s rules and forms, including controls and procedures designed to ensure that such information is accumulated and communicated to the Company’s management as appropriate to allow timely decisions regarding required disclosure.

(dd) Accounting Controls. The Company and its subsidiaries maintain systems of “internal control over financial reporting” (as defined in Rule 13a-15(f) of the Exchange Act) that comply with the requirements of the Exchange Act and have been designed by, or under the supervision of, their respective principal executive and principal financial officers, or persons performing similar functions, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with GAAP. The Company and its subsidiaries maintain internal accounting controls sufficient to provide reasonable assurance that (i) transactions are executed in accordance with management’s general or specific authorizations; (ii) transactions are recorded as necessary to permit preparation of financial statements in conformity with GAAP and to maintain asset accountability; (iii) access to assets is permitted only in accordance with management’s general or specific authorization; and (iv) the recorded accountability for assets is compared with the existing assets at reasonable intervals and appropriate action is taken with respect to any differences. There are no material weaknesses in the Company’s internal controls. The Company’s auditors and the relevant members of the board of directors of the Company have been advised of: (i) all significant deficiencies and material weaknesses, if any, in the design or operation of internal controls over financial reporting which have adversely affected or are reasonably likely to adversely affect the Company’s ability to record, process, summarize and report financial information; and (ii) any fraud, whether or not material, that involves management or other employees who have a significant role in the Company’s internal controls over financial reporting.

(ee) Insurance. (i) The Company and its subsidiaries are insured by VGLNG Insurance, LLC and by other insurers of recognized financial responsibility against such losses and risks and in such amounts as are prudent and customary in the business in which it is engaged and (ii) all such insurance is in full force and effect, except as would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect.

(ff) Cybersecurity; Data Protection. Except as disclosed in or contemplated by the Registration Statement, the Pricing Disclosure Package and the Prospectus (i) there has been no material security breach or incident, material unauthorized access or disclosure, or other material compromise relating to the Company’s and its subsidiaries’ information technology and computer systems, networks, hardware, software, data and databases (including the data and information of their respective customers, employees,

 

14


suppliers, vendors and any third party data maintained, processed or stored by the Company and its subsidiaries, and any such data processed or stored by third parties on behalf of the Company and its subsidiaries), equipment or technology (collectively, “IT Systems and Data”); (ii) neither the Company nor its subsidiaries have been notified of, and has no knowledge of any event or condition that would result in, any material security breach or incident, material unauthorized access or disclosure or other material compromise to their IT Systems and Data; (iii) the Company and its subsidiaries have implemented appropriate controls, policies, procedures, and technological safeguards designed to maintain and protect the integrity, continuous operation, redundancy and security of their IT Systems and Data reasonably consistent with industry standards and practices or as required by applicable regulatory standards; and (iv) the Company and its subsidiaries are presently in material compliance with all applicable laws or statutes and all judgments, orders, rules and regulations of any court or arbitrator or governmental or regulatory authority, internal policies and contractual obligations relating to the privacy and security of IT Systems and Data and to the protection of such IT Systems and Data from unauthorized use, access, misappropriation or modification.

(gg) No Unlawful Payments. (i) None of the Company, its subsidiaries, or any director or officer thereof, or to the Company’s knowledge, any employee, agent or affiliate of the Company or its subsidiaries or of any of such agent’s subsidiaries or affiliates acting on behalf of the Company or its subsidiaries, has taken any action in furtherance of an offer, payment, promise to pay, or authorization or approval of the payment or giving of money, property, gifts or anything else of value to any “government official” (including any officer or employee of a government or government-owned or controlled entity or of a public international organization, or any person acting in an official capacity for or on behalf of any of the foregoing, or any person holding a legislative, administrative or judicial office, or any political party or party official or candidate for political office) to influence official action, including the failure to perform an official function, or secure an improper advantage in violation of applicable anti-corruption laws;

(ii) the Company, its subsidiaries and their affiliates have conducted their businesses in compliance with applicable anti-corruption laws and have instituted and maintain and the Company and its subsidiaries will continue to maintain policies and procedures designed to promote and achieve compliance with such laws and with the representation and warranty contained herein;

(iii) neither the Company nor its subsidiaries will use, directly or indirectly, the proceeds of the offering in furtherance of an offer, payment, promise to pay, or authorization of the payment or giving of money, or anything else of value, to any person in violation of any applicable anti-corruption laws; and

(iv) there are no pending or, to the knowledge of the Company, threatened, legal proceedings, or, to the knowledge of the Company, any investigations by any governmental entity, with respect to violation of any anti-corruption laws, relating to the business of the Company or any of its subsidiaries.

 

15


(hh) Compliance with Anti-Money Laundering Laws. The operations of the Company and its subsidiaries are and have been conducted at all times in compliance with, in each case to the extent applicable, the financial recordkeeping and reporting requirements, including those of the Currency and Foreign Transactions Reporting Act of 1970 (commonly known as the Bank Secrecy Act), as amended by Title III of the Uniting and Strengthening America by Providing Appropriate Tools Required to Intercept and Obstruct Terrorism Act of 2001 (USA PATRIOT Act), and the anti-money laundering statutes of all jurisdictions where the Company and its subsidiaries conduct business, the rules and regulations thereunder and any related or similar rules, regulations or guidelines, issued, administered or enforced by any governmental agency (collectively, the “Anti-Money Laundering Laws”), and no action, suit or proceeding by or before any court or governmental agency, authority or body or any arbitrator involving the Company or any of its subsidiaries with respect to the Anti-Money Laundering Laws is pending or, to the knowledge of the Company, threatened.

(ii) No Conflicts with Sanctions Laws. (A) None of the Company, its subsidiaries or any directors or officers thereof, or to the knowledge of the Company, any agent or affiliate thereof, is an individual or entity (“Person”) that is currently:

(i) the target of any sanctions administered or enforced by the U.S. Department of the Treasury’s Office of Foreign Assets Control (“OFAC”) or the U.S. Department of State and including, without limitation, the designation as a “specially designated national” or “blocked person”, the United Nationals Security Council (“UNSC”), the European Union, His Majesty’s Treasury (“HMT”), or other relevant sanctions authority (collectively, “Sanctions”), nor

(ii) located, organized or resident in a country or territory that is currently the subject of Sanctions (including, without limitation, Crimea, Cuba, Iran, North Korea, Syria, the so-called Donetsk People’s Republic, the so-called Luhansk People’s Republic or any other Covered Region of Ukraine identified pursuant to Executive Order 14065).

(B) The Company represents and covenants that it will not, directly or indirectly, use the proceeds of the offering, or lend, contribute or otherwise make available such proceeds to any joint venture partner or other Person that is, at the time of such transaction:

(i) the target of any Sanctions, nor

(ii) located, organized or resident in a country or territory that is the subject of Sanctions.

 

16


(jj) No Restrictions on Subsidiaries. No subsidiary of the Company is currently prohibited, directly or indirectly, under any agreement or other instrument to which it is a party or is subject, from paying any dividends to the Company, from making any other distribution on such subsidiary’s capital stock or similar ownership interest, from repaying to the Company any loans or advances to such subsidiary from the Company or from transferring any of such subsidiary’s properties or assets to the Company or any other subsidiary of the Company (in each case, other than (A) as disclosed or contemplated by the Registration Statement, the Pricing Disclosure Package and the Prospectus, or (B) pursuant to, or as otherwise permitted under the terms of, the existing indebtedness of the Company and its subsidiaries described under the “Description of Material Financing” section of the Registration Statement, the Pricing Disclosure Package and the Prospectus).

(kk) No Broker’s Fees. Neither the Company nor any of its subsidiaries is a party to any contract, agreement or understanding with any person (other than this Agreement) that would give rise to a valid claim against any of them or any Underwriter for a brokerage commission, finder’s fee or like payment in connection with the offering and sale of the Shares.

(ll) No Registration Rights. Except as disclosed in or contemplated by the Registration Statement, the Pricing Disclosure Package and the Prospectus, no person has the right to require the Company or any of its subsidiaries to register any securities for sale under the Securities Act by reason of the filing of the Registration Statement with the Commission or the issuance and sale of the Shares.

(mm) No Stabilization. Neither the Company nor any of its subsidiaries or affiliates has taken, directly or indirectly, any action designed to or that could reasonably be expected to cause or result in any stabilization or manipulation of the price of the Shares.

(nn) Margin Rules. Neither the issuance, sale and delivery of the Shares nor the application of the proceeds thereof by the Company as described in each of the Registration Statement, the Pricing Disclosure Package and the Prospectus will violate Regulation T, U or X of the Board of Governors of the Federal Reserve System or any other regulation of such Board of Governors.

(oo) Forward-Looking Statements. No forward-looking statement (within the meaning of Section 27A of the Securities Act and Section 21E of the Exchange Act) included in any of the Registration Statement, the Pricing Disclosure Package or the Prospectus has been made or reaffirmed without a reasonable basis or has been disclosed other than in good faith.

(pp) Statistical and Market Data. Nothing has come to the attention of the Company that has caused the Company to believe that the statistical and market-related data included in each of the Registration Statement, the Pricing Disclosure Package and the Prospectus is not based on or derived from sources that are reliable and accurate in all material respects.

 

17


(qq) Sarbanes-Oxley Act. There is and has been no failure on the part of the Company or any of the Company’s directors or officers, in their capacities as such, to comply with any provision of the Sarbanes-Oxley Act of 2002, as amended and the rules and regulations promulgated in connection therewith (the “Sarbanes-Oxley Act”), including Section 402 related to loans and Sections 302 and 906 related to certifications.

(rr) Status under the Securities Act. At the time of filing the Registration Statement and any post-effective amendment thereto, at the earliest time thereafter that the Company or any offering participant made a bona fide offer (within the meaning of Rule 164(h)(2) under the Securities Act) of the Shares and at the date hereof, the Company was not and is not an “ineligible issuer,” as defined in Rule 405 under the Securities Act.

4. Further Agreements of the Company. The Company covenants and agrees with each Underwriter that:

(a) Required Filings. The Company will file the final Prospectus with the Commission within the earlier of (i) the Closing Date and (ii) the time periods specified by Rule 424(b) and Rule 430A, 430B or 430C under the Securities Act, will file any Issuer Free Writing Prospectus to the extent required by Rule 433 under the Securities Act.

(b) Delivery of Copies. The Company will deliver, if requested, without charge, (i) to the Representatives, three signed copies of the Registration Statement as originally filed and each amendment thereto, in each case including all exhibits and consents filed therewith; and (ii) to each Underwriter (A) a conformed copy of the Registration Statement as originally filed and each amendment thereto (without exhibits) and (B) during the Prospectus Delivery Period (as defined below), as many copies of the Prospectus (including all amendments and supplements thereto and each Issuer Free Writing Prospectus) as the Representatives may reasonably request. As used herein, the term “Prospectus Delivery Period” means such period of time after the first date of the public offering of the Shares as in the opinion of counsel for the Underwriters a prospectus relating to the Shares is required by law to be delivered (or required to be delivered but for Rule 172 under the Securities Act) in connection with sales of the Shares by any Underwriter or dealer.

(c) Amendments or Supplements, Issuer Free Writing Prospectuses. Before making, preparing, using, authorizing, approving, referring to or filing any Issuer Free Writing Prospectus, and before filing any amendment or supplement to the Registration Statement, the Pricing Disclosure Package or the Prospectus, the Company will furnish to the Representatives and counsel for the Underwriters a copy of the proposed Issuer Free Writing Prospectus, amendment or supplement for review and will not make, prepare, use, authorize, approve, refer to or file any such Issuer Free Writing Prospectus or file any such proposed amendment or supplement to which the Representatives reasonably objects.

 

18


(d) Notice to the Representatives. The Company will advise the Representatives promptly, and confirm such advice in writing (which may be by electronic mail), (i) when the Registration Statement has become effective; (ii) when any amendment to the Registration Statement has been filed or becomes effective; (iii) when any supplement to the Pricing Disclosure Package, the Prospectus, any Issuer Free Writing Prospectus or any Written Testing-the-Waters Communication or any amendment to the Prospectus has been filed or distributed; (iv) of any request by the Commission for any amendment to the Registration Statement or any amendment or supplement to the Prospectus or the receipt of any comments from the Commission relating to the Registration Statement or any other request by the Commission for any additional information including, but not limited to, any request for information concerning any Testing-the-Waters Communication; (v) of the issuance by the Commission or any other governmental or regulatory authority of any order suspending the effectiveness of the Registration Statement or preventing or suspending the use of any Preliminary Prospectus, any of the Pricing Disclosure Package, the Prospectus or any Written Testing-the-Waters Communication or the initiation or, to the knowledge of the Company, threatening of any proceeding for that purpose or pursuant to Section 8A of the Securities Act; (vi) of the occurrence of any event or development within the Prospectus Delivery Period as a result of which the Prospectus, any of the Pricing Disclosure Package, any Issuer Free Writing Prospectus or any Written Testing-the-Waters Communication as then amended or supplemented would include any untrue statement of a material fact or omit to state a material fact necessary in order to make the statements therein, in the light of the circumstances existing when the Prospectus, the Pricing Disclosure Package, any such Issuer Free Writing Prospectus or any Written Testing-the-Waters Communication is delivered to a purchaser, not misleading; and (vii) of the receipt by the Company of any notice with respect to any suspension of the qualification of the Shares for offer and sale in any jurisdiction or the initiation or, to the knowledge of the Company, threatening of any proceeding for such purpose; and the Company will use its reasonable best efforts to prevent the issuance of any such order suspending the effectiveness of the Registration Statement, preventing or suspending the use of any Preliminary Prospectus, any of the Pricing Disclosure Package or the Prospectus or any Written Testing-the-Waters Communication or suspending any such qualification of the Shares and, if any such order is issued, will use its reasonable best efforts to obtain as soon as possible the withdrawal thereof.

(e) Ongoing Compliance. (1) If during the Prospectus Delivery Period (i) any event or development shall occur or condition shall exist as a result of which the Prospectus as then amended or supplemented would include any untrue statement of a material fact or omit to state any material fact necessary in order to make the statements therein, in the light of the circumstances existing when the Prospectus is delivered to a purchaser, not misleading or (ii) it is necessary to amend or supplement the Prospectus to comply with applicable law, the Company will promptly notify the Underwriters thereof and forthwith prepare and, subject to paragraph (c) above, file with the Commission and furnish to the Underwriters and to such dealers as the Representatives may designate such amendments or supplements to the Prospectus as may be necessary so that the statements in the Prospectus as so amended or supplemented will not, in the light of the circumstances existing when the Prospectus is delivered to a purchaser, be misleading or so that the Prospectus will comply with law and (2) if at any time prior to the Closing Date (i) any event or development shall occur or condition shall exist as a result of which

 

19


the Pricing Disclosure Package as then amended or supplemented would include any untrue statement of a material fact or omit to state any material fact necessary in order to make the statements therein, in the light of the circumstances existing when the Pricing Disclosure Package is delivered to a purchaser, not misleading or (ii) it is necessary to amend or supplement the Pricing Disclosure Package to comply with applicable law, the Company will promptly notify the Underwriters thereof and forthwith prepare and, subject to paragraph (c) above, file with the Commission (to the extent required) and furnish to the Underwriters and to such dealers as the Representatives may designate such amendments or supplements to the Pricing Disclosure Package as may be necessary so that the statements in the Pricing Disclosure Package as so amended or supplemented will not, in the light of the circumstances existing when the Pricing Disclosure Package is delivered to a purchaser, be misleading or so that the Pricing Disclosure Package will comply with applicable law.

(f) Blue Sky Compliance. The Company will qualify the Shares for offer and sale under the securities or Blue Sky laws of such jurisdictions as the Representatives shall reasonably request and will continue such qualifications in effect so long as required for distribution of the Shares; provided that the Company shall not be required to (i) qualify as a foreign corporation or other entity or as a dealer in securities in any such jurisdiction where it would not otherwise be required to so qualify, (ii) file any general consent to service of process in any such jurisdiction or (iii) subject itself to taxation in any such jurisdiction if it is not otherwise so subject.

(g) Earning Statement. The Company will make generally available to its security holders and the Representatives as soon as practicable an earning statement that satisfies the provisions of Section 11(a) of the Securities Act and Rule 158 of the Commission promulgated thereunder covering a period of at least twelve months beginning with the first fiscal quarter of the Company occurring after the “effective date” (as defined in Rule 158) of the Registration Statement; provided that the Company will be deemed to comply with such requirement by furnishing such earnings statements on the Commission’s Electronic, Data Gathering, Analysis and Retrieval System (“EDGAR”) (or any successor system).

(h) Clear Market. For a period of 180 days after the date of the Prospectus (the “Restricted Period”), the Company will not (i) offer, pledge, sell, contract to sell, sell any option or contract to purchase, purchase any option or contract to sell, grant any option, right or warrant to purchase, lend, or otherwise transfer or dispose of, directly or indirectly, or submit to, or file with, the Commission a registration statement under the Securities Act relating to, any shares of Stock or any securities convertible into or exercisable or exchangeable for Stock, or publicly disclose the intention to undertake any of the foregoing, or (ii) enter into any swap or other agreement that transfers, in whole or in part, any of the economic consequences of ownership of the Stock or any such other securities, whether any such transaction described in clause (i) or (ii) above is to be settled by delivery of Stock or such other securities, in cash or otherwise, without the prior written consent of the Representatives, other than the Shares to be sold hereunder.

 

20


The restrictions described above do not apply to (i) the Shares to be sold hereunder; (ii) the conversion of certain shares of Class A Common Stock into Class B Common Stock, par value $0.01 per share (“Class B Common Stock”), of the Company as described in the Registration Statement, the Pricing Disclosure Package and the Prospectus; (iii) the establishment or amendment of a trading plan on behalf of a stockholder, officer or director of the Company pursuant to Rule 10b5-1 under the Exchange Act for the transfer of shares of Class A Common Stock, provided that (A) such plan does not provide for the transfer of Class A Common Stock during the Restricted Period and (B) to the extent a public announcement or filing under the Exchange Act, if any, is required of or voluntarily made by the Company regarding the establishment of such plan, such announcement or filing shall include a statement to the effect that no transfer of Class A Common Stock may be made under such plan during the Restricted Period; (iv) the offer or issuance or agreement to issue by the Company of Class A Common Stock or securities convertible into, exercisable for or which are otherwise exchangeable for or represent the right to receive Class A Common Stock in connection with an acquisition, merger, joint venture, strategic alliance, commercial or other collaborative relationship or the acquisition or license by the Company or any of its subsidiaries of the securities, business, property or other assets of another person or entity or pursuant to any employee benefit plan as assumed by the Company in connection with any such acquisition or transaction, provided that the aggregate number of shares of Class A Common Stock, securities convertible into, exercisable for or which are otherwise exchangeable for or represent the right to receive Class A Common Stock that the Company may sell or issue or agree to sell or issue pursuant to this clause (iv) shall not exceed 10.0% of the total number of shares of Stock outstanding immediately following the issuance of the Shares hereunder and provided further that, with respect to this clause (iv), the recipients thereof provide to the Representatives a signed lock-up agreement substantially in the form of the lock-up agreement described in Section 6(l) hereof; (v) conversions of Class B Common Stock into Class A Common Stock pursuant to the terms of the Company’s certificate of incorporation; (vi) the issuance of shares of Class A Common Stock or securities convertible into or exercisable for shares of Class A Common Stock pursuant to the conversion or exchange of convertible or exchangeable securities or the exercise of warrants or options or similar awards (including net exercise) or the settlement of RSUs or other equity-based awards (including net settlement) as described in the Prospectus; (vii) grants of stock options, stock awards, restricted stock, RSUs, or other equity or equity-based awards and the issuance of shares of Class A Common Stock or securities convertible into or exercisable or exchangeable for shares of Class A Common Stock (whether upon the exercise of stock options or otherwise) to the Company’s employees, officers, directors, advisors, consultants or prospective employees or officers, pursuant to the terms of an equity compensation plan described in the Prospectus; or (viii) the filing of any registration statement on Form S-8 relating to securities granted or to be granted pursuant to any equity compensation plan described in the Prospectus. Notwithstanding the foregoing, the issuance of shares of Class A Common Stock pursuant to the exercise of options under the 2023 Stock Option Plan shall only be permitted if the recipients of such shares are subject to certain market stand-off provisions pursuant to the 2023 Stock Option Plan (which the Company agrees not to waive without the prior consent of the Representatives) or enter into a lock-up agreement with the Representatives substantially in the form of the lock-up agreement described in Section 6(l) hereof.

 

21


If the Representatives, in their sole discretion, agree to release or waive the restrictions set forth in a lock-up agreement described in Section 6(l) hereof for an officer or director of the Company and provide the Company with notice of the impending release or waiver substantially in the form of Exhibit B hereto at least three business days before the effective date of the release or waiver, the Company agrees to announce the impending release or waiver substantially in the form of Exhibit C hereto through a major news service at least two business days before the effective date of the release or waiver.

(i) Use of Proceeds. The Company will apply the net proceeds from the sale of the Shares as described in each of the Registration Statement, the Pricing Disclosure Package and the Prospectus under the heading “Use of proceeds”.

(j) No Stabilization. Neither the Company nor its subsidiaries or affiliates will take, directly or indirectly, any action designed to or that could reasonably be expected to cause or result in any stabilization or manipulation of the price of the Stock.

(k) Exchange Listing. The Company will use its reasonable best efforts to list, subject to notice of issuance, the Shares on the Exchange.

(l) Reports. For a period of two years from the date of this Agreement, the Company will furnish to the Representatives, as soon as they are available, copies of all reports or other communications (financial or other) furnished to holders of the Shares in their capacity as such, and copies of any reports and financial statements furnished to or filed with the Commission or any national securities exchange or automatic quotation system; provided the Company will be deemed to have furnished such reports and financial statements to the Representatives to the extent they are filed on EDGAR.

(m) Record Retention. The Company will, pursuant to reasonable procedures developed in good faith, retain copies of each Issuer Free Writing Prospectus that is not filed with the Commission in accordance with Rule 433 under the Securities Act.

(n) Filings. The Company will file with the Commission such reports as may be required by Rule 463 under the Securities Act.

5. Certain Agreements of the Underwriters. Each Underwriter hereby represents and agrees that:

(a) It has not and will not use, authorize use of, refer to or participate in the planning for use of, any “free writing prospectus”, as defined in Rule 405 under the Securities Act (which term includes use of any written information furnished to the Commission by the Company and not incorporated by reference into the Registration Statement and any press release issued by the Company) other than (i) a free writing prospectus that contains no “issuer information” (as defined in Rule 433(h)(2) under the

 

22


Securities Act) that was not included (including through incorporation by reference) in the Preliminary Prospectus or a previously filed Issuer Free Writing Prospectus, (ii) any Issuer Free Writing Prospectus listed on Annex A or prepared pursuant to Section 3(c) or Section 4(c) above (including any electronic road show approved in advance by the Company), or (iii) any free writing prospectus prepared by such Underwriter and approved by the Company in advance in writing (each such free writing prospectus referred to in clauses (i) or (iii), an “Underwriter Free Writing Prospectus”).

(b) It has not and will not, without the prior written consent of the Company, use any free writing prospectus that contains the final terms of the Shares unless such terms have previously been included in a free writing prospectus filed with the Commission; provided that Underwriters may use a term sheet substantially in the form of Annex C hereto without the consent of the Company; provided further that any Underwriter using such term sheet shall notify the Company, and provide a copy of such term sheet to the Company, prior to, or substantially concurrently with, the first use of such term sheet.

(c) It is not subject to any pending proceeding under Section 8A of the Securities Act with respect to the offering (and will promptly notify the Company if any such proceeding against it is initiated during the Prospectus Delivery Period).

6. Conditions of Underwriters’ Obligations. The obligation of each Underwriter to purchase the Underwritten Shares on the Closing Date or the Option Shares on the Additional Closing Date, as the case may be, as provided herein is subject to the performance by the Company of its covenants and other obligations hereunder and to the following additional conditions:

(a) Registration Compliance; No Stop Order. No order suspending the effectiveness of the Registration Statement shall be in effect, and no proceeding for such purpose or pursuant to Section 8A under the Securities Act shall be pending before or, to the knowledge of the Company, threatened by the Commission; the Prospectus and each Issuer Free Writing Prospectus shall have been timely filed with the Commission under the Securities Act (in the case of an Issuer Free Writing Prospectus, to the extent required by Rule 433 under the Securities Act) and in accordance with Section 4(a) hereof; and all requests by the Commission for additional information shall have been complied with to the reasonable satisfaction of the Representatives.

(b) Representations and Warranties. The representations and warranties of the Company contained herein shall be true and correct on the date hereof and on and as of the Closing Date or the Additional Closing Date, as the case may be; and the statements of the Company and its officers made in any certificates delivered pursuant to this Agreement shall be true and correct on and as of the Closing Date or the Additional Closing Date, as the case may be.

(c) No Downgrade. Subsequent to the earlier of (A) the Applicable Time and (B) the execution and delivery of this Agreement, (i) no downgrading shall have occurred in the rating accorded any debt securities, convertible securities or preferred stock issued, or guaranteed by, the Company or any of its subsidiaries by any “nationally recognized statistical rating organization,” as such term is defined under Section 3(a)(62) under the Exchange Act and (ii) no such organization shall have publicly announced that it has under surveillance or review, or has changed its outlook with respect to, its rating of any such debt securities or preferred stock issued or guaranteed by the Company or any of its subsidiaries (other than an announcement with positive implications of a possible upgrading).

 

23


(d) No Material Adverse Change. No event or condition of a type described in Section 3(g) hereof shall have occurred or shall exist, which event or condition is not described in the Pricing Disclosure Package (excluding any amendment or supplement thereto) and the Prospectus (excluding any amendment or supplement thereto) and the effect of which in the judgment of the Representatives makes it impracticable or inadvisable to proceed with the offering, sale or delivery of the Shares on the Closing Date or the Additional Closing Date, as the case may be, on the terms and in the manner contemplated by this Agreement, the Pricing Disclosure Package and the Prospectus.

(e) Officer’s Certificate. The Representatives shall have received on and as of the Closing Date or the Additional Closing Date, as the case may be, a certificate of principal financial or accounting officer of the Company on behalf of the Company, and not in their personal capacities (i) confirming that such officers have carefully reviewed the Registration Statement, the Pricing Disclosure Package and the Prospectus and, to the knowledge of such officers, the representations set forth in Sections 3(b) and 3(d) hereof are true and correct, (ii) confirming that the other representations and warranties of the Company in this Agreement are true and correct and that the Company has complied in all material respects with all agreements and satisfied all conditions on its part to be performed or satisfied hereunder at or prior to the Closing Date or the Additional Closing Date, as the case may be, and (iii) to the effect set forth in paragraphs (a), (c) and (d) above.

(f) Comfort Letters. On the date of this Agreement and on the Closing Date or the Additional Closing Date, as the case may be, Ernst & Young LLP shall have furnished to the Representatives, at the request of the Company, letters, dated the respective dates of delivery thereof and addressed to the Underwriters, in form and substance reasonably satisfactory to the Representatives, containing statements and information of the type customarily included in accountants’ “comfort letters” to underwriters with respect to the financial statements and certain financial information contained in each of the Registration Statement, the Pricing Disclosure Package and the Prospectus; provided, that the letter delivered on the Closing Date or the Additional Closing Date, as the case may be, shall use a “cut-off” date no more than two business days prior to such Closing Date or such Additional Closing Date, as the case may be.

(g) Opinion and 10b-5 Statement of Counsel for the Company. The Representatives shall have received on the Closing Date or the Additional Closing Date, as the case may be, (i) an opinion of Davis Polk & Wardwell LLP, counsel for the Company, in form and substance reasonably satisfactory to the Representatives, (ii) a

 

24


negative assurance letter of Davis Polk & Wardwell LLP, counsel for the Company, in form and substance reasonably satisfactory to the Representatives and (iii) an opinion of Latham & Watkins LLP, in form and substance reasonably satisfactory to the Representatives. Such opinions and letter shall be dated as of the Closing Date or the Additional Closing Date, as the case may be, and rendered to the Underwriters at the request of the Company and shall so state therein.

(h) Opinion and 10b-5 Statement of Counsel for the Underwriters. The Representatives shall have received on and as of the Closing Date or the Additional Closing Date, as the case may be, an opinion and 10b-5 statement, addressed to the Underwriters, of Skadden, Arps, Slate, Meagher & Flom LLP, counsel for the Underwriters, with respect to such matters as the Representatives may reasonably request, and such counsel shall have received such documents and information as they may reasonably request to enable them to pass upon such matters.

(i) No Legal Impediment to Issuance and Sale. No action shall have been taken and no statute, rule, regulation or order shall have been enacted, adopted or issued by any federal, state or foreign governmental or regulatory authority that would, as of the Closing Date or the Additional Closing Date, as the case may be, prevent the issuance or sale of the Shares; and no injunction or order of any federal, state or foreign court shall have been issued that would, as of the Closing Date or the Additional Closing Date, as the case may be, prevent the issuance or sale of the Shares.

(j) Good Standing. The Representatives shall have received on and as of the Closing Date or the Additional Closing Date, as the case may be, satisfactory evidence of the good standing of the Company and its Significant Subsidiaries in their respective jurisdictions of organization and their good standing in such other jurisdictions (to the extent the concept of good standing is applicable in such other jurisdictions) as the Representatives may reasonably request, in each case in writing or any standard form of telecommunication from the appropriate governmental authorities of such jurisdictions.

(k) Exchange Listing. The Shares to be delivered on the Closing Date or the Additional Closing Date, as the case may be, shall have been approved for listing on the Exchange, subject to official notice of issuance.

(l) Lock-up Agreements. The “lock-up” agreements, each substantially in the form of Exhibit D hereto, between you and certain shareholders, officers and directors of the Company relating to sales and certain other dispositions of shares of Stock or certain other securities, delivered to you on or before the date hereof, shall be full force and effect on the Closing Date or the Additional Closing Date, as the case may be.

(m) Additional Documents. On or prior to the Closing Date or the Additional Closing Date, as the case may be, the Company shall have furnished to the Representatives such further certificates and documents as the Representatives may reasonably request.

 

25


7. Indemnification and Contribution.

(a) Indemnification of the Underwriters. The Company agrees to indemnify and hold harmless each Underwriter, its affiliates, directors and officers and each person, if any, who controls such Underwriter within the meaning of Section 15 of the Securities Act or Section 20 of the Exchange Act, from and against any and all losses, claims, damages and liabilities (including, without limitation, reasonable and documented legal fees and other reasonable and documented expenses incurred in connection with any suit, action or proceeding or any claim asserted, as such fees and expenses are incurred), joint or several, that arise out of, or are based upon, (i) any untrue statement or alleged untrue statement of a material fact contained in the Registration Statement or caused by any omission or alleged omission to state therein a material fact required to be stated therein or necessary in order to make the statements therein, not misleading, or (ii) any untrue statement or alleged untrue statement of a material fact contained in the Prospectus (or any amendment or supplement thereto), any Preliminary Prospectus, any Issuer Free Writing Prospectus, any “issuer information” filed or required to be filed pursuant to Rule 433(d) under the Securities Act, any Written Testing-the-Waters Communication prepared or authorized by the Company, any road show as defined in Rule 433(h) under the Securities Act (a “road show”) or any Pricing Disclosure Package (including any Pricing Disclosure Package that has subsequently been amended), or caused by any omission or alleged omission to state therein a material fact necessary in order to make the statements therein, in the light of the circumstances under which they were made, not misleading, in each case except insofar as such losses, claims, damages or liabilities arise out of, or are based upon, any untrue statement or omission or alleged untrue statement or omission made in reliance upon and in conformity with any information relating to any Underwriter furnished to the Company in writing by such Underwriter through the Representatives expressly for use therein, it being understood and agreed that the only such information furnished by any Underwriter consists of the information described as such in paragraph (b) below.

(b) Indemnification of the Company. Each Underwriter agrees, severally and not jointly, to indemnify and hold harmless the Company, its directors, its officers who signed the Registration Statement and each person, if any, who controls the Company within the meaning of Section 15 of the Securities Act or Section 20 of the Exchange Act to the same extent as the indemnity set forth in paragraph (a) above, but only with respect to any losses, claims, damages or liabilities that arise out of, or are based upon, any untrue statement or omission or alleged untrue statement or omission made in reliance upon and in conformity with any information relating to such Underwriter furnished to the Company in writing by such Underwriter through the Representatives expressly for use in the Registration Statement, the Prospectus (or any amendment or supplement thereto), any Preliminary Prospectus, any Issuer Free Writing Prospectus, any Written Testing-the-Waters Communication, any road show or any Pricing Disclosure Package (including any Pricing Disclosure Package that has subsequently been amended), it being understood and agreed upon that the only such information furnished by any Underwriter consists of the following information in the Prospectus furnished on behalf of each Underwriter: the concession and reallowance figures appearing in the [•] paragraph under the caption “Underwriting”, the information contained in the [•] paragraph under the caption “Underwriting” and the following information in the Prospectus furnished on behalf of [•].

 

26


(c) Notice and Procedures. If any suit, action, proceeding (including any governmental or regulatory investigation), claim or demand shall be brought or asserted against any person in respect of which indemnification may be sought pursuant to the preceding paragraphs of this Section 7, such person (the “Indemnified Person”) shall promptly notify the person against whom such indemnification may be sought (the “Indemnifying Person”) in writing; provided that the failure to notify the Indemnifying Person shall not relieve it from any liability that it may have under the preceding paragraphs of this Section 7 except to the extent that it has been materially prejudiced (through the forfeiture of substantive rights or defenses) by such failure; and provided further, that the failure to notify the Indemnifying Person shall not relieve it from any liability that it may have to an Indemnified Person otherwise than under the preceding paragraphs of this Section 7. If any such proceeding shall be brought or asserted against an Indemnified Person and it shall have notified the Indemnifying Person thereof, the Indemnifying Person shall be entitled to participate therein and, to the extent that it may wish, jointly with any other Indemnifying Person similarly notified, to assume the defense thereof, with counsel reasonably satisfactory to the Indemnified Person (who shall not, except with the consent of the Indemnified Person, be counsel to the Indemnifying Person), and after notice from the Indemnifying Person to such Indemnified Person of its election so to assume the defense thereof, the Indemnifying Person will not be liable to such Indemnified Person under this Section 7 for any legal or other expenses subsequently incurred by such Indemnified Person in connection with the defense thereof other than reasonable and documented costs of investigation. In any such proceeding, any Indemnified Person shall have the right to retain its own counsel, but the fees and expenses of such counsel shall be at the expense of such Indemnified Person unless (i) the Indemnifying Person and the Indemnified Person shall have mutually agreed to the contrary; (ii) the Indemnifying Person has failed within a reasonable time to retain counsel reasonably satisfactory to the Indemnified Person; (iii) the Indemnified Person shall have reasonably concluded that there may be legal defenses available to it that are different from or in addition to those available to the Indemnifying Person; or (iv) the named parties in any such proceeding (including any impleaded parties) include both the Indemnifying Person and the Indemnified Person and representation of both parties by the same counsel would be inappropriate due to actual or potential differing interests between them. It is understood and agreed that the Indemnifying Person shall not, in connection with any proceeding or related proceeding in the same jurisdiction, be liable for the reasonably incurred and documented fees and expenses of more than one separate firm (in addition to any local counsel) for all Indemnified Persons, and that all such reasonably incurred and documented fees and expenses shall be paid or reimbursed as they are incurred. Any such separate firm for any Underwriter, its affiliates, directors and officers and any control persons of such Underwriter shall be designated in writing by the Representatives and any such separate firm for the Company, its directors, its officers who signed the Registration Statement and any control persons of the Company shall be designated in writing by the Company. No Indemnifying Person shall, without the written consent of the Indemnified Person, effect any settlement of any pending or threatened proceeding in respect of which any Indemnified Person is or could have been a party and indemnification could have been sought hereunder by such Indemnified Person, unless such settlement (x) includes an unconditional release of such Indemnified Person, in form and substance reasonably satisfactory to such Indemnified Person, from all liability on claims that are the subject matter of such proceeding and (y) does not include any statement as to or any admission of fault, culpability or a failure to act by or on behalf of any Indemnified Person.

 

27


(d) Contribution. If the indemnification provided for in paragraphs (a) or (b) above is unavailable to an Indemnified Person or insufficient in respect of any losses, claims, damages or liabilities referred to therein, then each Indemnifying Person under such paragraph, in lieu of indemnifying such Indemnified Person thereunder, shall contribute to the amount paid or payable by such Indemnified Person as a result of such losses, claims, damages or liabilities (i) in such proportion as is appropriate to reflect the relative benefits received by the Company, on the one hand, and the Underwriters on the other, from the offering of the Shares or (ii) if the allocation provided by clause (i) is not permitted by applicable law, in such proportion as is appropriate to reflect not only the relative benefits referred to in clause (i) but also the relative fault of the Company, on the one hand, and the Underwriters on the other, in connection with the statements or omissions that resulted in such losses, claims, damages or liabilities, as well as any other relevant equitable considerations. The relative benefits received by the Company, on the one hand, and the Underwriters on the other, shall be deemed to be in the same respective proportions as the net proceeds (before deducting expenses) received by the Company from the sale of the Shares and the total underwriting discounts and commissions received by the Underwriters in connection therewith, in each case as set forth in the table on the cover of the Prospectus, bear to the aggregate offering price of the Shares. The relative fault of the Company, on the one hand, and the Underwriters on the other, shall be determined by reference to, among other things, whether the untrue or alleged untrue statement of a material fact or the omission or alleged omission to state a material fact relates to information supplied by the Company or by the Underwriters and the parties’ relative intent, knowledge, access to information and opportunity to correct or prevent such statement or omission.

(e) Limitation on Liability. The Company and the Underwriters agree that it would not be just and equitable if contribution pursuant to paragraph (d) above were determined by pro rata allocation (even if the Underwriters were treated as one entity for such purpose) or by any other method of allocation that does not take account of the equitable considerations referred to in paragraph (d) above. The amount paid or payable by an Indemnified Person as a result of the losses, claims, damages and liabilities referred to in paragraph (d) above shall be deemed to include, subject to the limitations set forth above, any documented legal or other expenses reasonably incurred by such Indemnified Person in connection with any such action or claim. Notwithstanding the provisions of paragraphs (d) and (e), in no event shall an Underwriter be required to contribute any amount in excess of the amount by which the total underwriting discounts and commissions received by such Underwriter with respect to the offering of the Shares exceeds the amount of any damages that such Underwriter has otherwise been required to pay by reason of such untrue or alleged untrue statement or omission or alleged omission. No person guilty of fraudulent misrepresentation (within the meaning of Section 11(f) of the Securities Act) shall be entitled to contribution from any person who was not guilty of such fraudulent misrepresentation. The Underwriters’ obligations to contribute pursuant to paragraphs (d) and (e) are several in proportion to their respective purchase obligations hereunder and not joint.

(f) Non-Exclusive Remedies. The remedies provided for in [paragraphs (a) through (e)] are not exclusive and shall not limit any rights or remedies which may otherwise be available to any Indemnified Person at law or in equity.

 

28


8. Effectiveness of Agreement. This Agreement shall become effective as of the date first written above.

9. Termination. This Agreement may be terminated in the absolute discretion of the Representatives, by notice to the Company, if after the execution and delivery of this Agreement and on or prior to the Closing Date or, in the case of the Option Shares, prior to the Additional Closing Date (i) trading generally shall have been suspended or materially limited on or by any of the Exchange or The Nasdaq Stock Market; (ii) trading of any securities issued or guaranteed by the Company shall have been suspended on any exchange or in any over-the-counter market; (iii) a general moratorium on commercial banking activities shall have been declared by federal or New York State authorities; or (iv) there shall have occurred any outbreak or escalation of hostilities or any change in financial markets or any calamity or crisis, either within or outside the United States, that, in the judgment of the Representatives, is material and adverse and makes it impracticable or inadvisable to proceed with the offering, sale or delivery of the Shares on the Closing Date or the Additional Closing Date, as the case may be, on the terms and in the manner contemplated by this Agreement, the Pricing Disclosure Package and the Prospectus.

10. Defaulting Underwriter.

(a) If, on the Closing Date or the Additional Closing Date, as the case may be, any Underwriter defaults on its obligation to purchase the Shares that it has agreed to purchase hereunder on such date, the non-defaulting Underwriters may in their discretion arrange for the purchase of such Shares by other persons satisfactory to the Company on the terms contained in this Agreement. If, within 36 hours after any such default by any Underwriter, the non-defaulting Underwriters do not arrange for the purchase of such Shares, then the Company shall be entitled to a further period of 36 hours within which to procure other persons satisfactory to the non-defaulting Underwriters to purchase such Shares on such terms. If other persons become obligated or agree to purchase the Shares of a defaulting Underwriter, either the non-defaulting Underwriters or the Company may postpone the Closing Date or the Additional Closing Date, as the case may be, for up to five full business days in order to effect any changes that in the opinion of counsel for the Company or counsel for the Underwriters may be necessary in the Registration Statement and the Prospectus or in any other document or arrangement, and the Company agrees to promptly prepare any amendment or supplement to the Registration Statement and the Prospectus that effects any such changes. As used in this Agreement, the term “Underwriter” includes, for all purposes of this Agreement unless the context otherwise requires, any person not listed in Schedule 1 hereto that, pursuant to this Section 10, purchases Shares that a defaulting Underwriter agreed but failed to purchase.

(b) If, after giving effect to any arrangements for the purchase of the Shares of a defaulting Underwriter or Underwriters by the non-defaulting Underwriters and the Company as provided in paragraph (a) above, the aggregate number of Shares that remain unpurchased on the Closing Date or the Additional Closing Date, as the case may be, does not exceed one-eleventh of the aggregate number of Shares to be purchased on such date, then the Company shall have the right to require each non-defaulting Underwriter to purchase the number of Shares that such Underwriter agreed to purchase hereunder on such date plus such Underwriter’s pro rata share (based on the number of Shares that such Underwriter agreed to purchase on such date) of the Shares of such defaulting Underwriter or Underwriters for which such arrangements have not been made.

 

29


(c) If, after giving effect to any arrangements for the purchase of the Shares of a defaulting Underwriter or Underwriters by the non-defaulting Underwriters and the Company as provided in paragraph (a) above, the aggregate number of Shares that remain unpurchased on the Closing Date or the Additional Closing Date, as the case may be, exceeds one-eleventh of the aggregate amount of Shares to be purchased on such date, or if the Company shall not exercise the right described in paragraph (b) above, then this Agreement or, with respect to any Additional Closing Date, the obligation of the Underwriters to purchase Shares on the Additional Closing Date, as the case may be, shall terminate without liability on the part of the non-defaulting Underwriters. Any termination of this Agreement pursuant to this Section 10 shall be without liability on the part of the Company, except that the Company and the Underwriters will continue to be liable for the payment of expenses as set forth in Section 11 hereof and except that the provisions of Section 7 hereof shall not terminate and shall remain in effect.

(d) Nothing contained herein shall relieve a defaulting Underwriter of any liability it may have to the Company or any non-defaulting Underwriter for damages caused by its default.

11. Payment of Expenses.

(a) Whether or not the transactions contemplated by this Agreement are consummated or this Agreement is terminated, the Company will pay or cause to be paid all costs and expenses incident to the performance of its obligations hereunder, including without limitation, (i) the costs incident to the authorization, issuance, sale, preparation and delivery of the Shares and any taxes payable in that connection; (ii) the costs incident to the preparation, printing and filing under the Securities Act of the Registration Statement, the Preliminary Prospectus, any Issuer Free Writing Prospectus, any Pricing Disclosure Package and the Prospectus (including all exhibits, amendments and supplements thereto) and the distribution thereof; (iii) the fees and expenses of the Company’s counsel and independent accountants; (iv) the fees and expenses incurred in connection with the registration or qualification and determination of eligibility for investment of the Shares under the laws of such jurisdictions as the Representatives may designate and the preparation, printing and distribution of a Blue Sky Memorandum (including the related reasonable and documented fees and expenses of counsel for the Underwriters); (v) the cost of preparing stock certificates, if applicable; (vi) the costs and charges of any transfer agent and any registrar; (vii) all expenses and application fees incurred in connection with any filing with, and clearance of the offering by, FINRA, provided that the Underwriters’ counsel fees and expenses pursuant to clauses (iv) and (vii) shall not, in the aggregate, exceed $50,000; (viii) all expenses incurred by the Company in connection with any “road show” presentation to potential investors, provided, however, the Company and the Underwriters shall each pay 50% of the total costs of chartering any aircraft to be used in connection with any such “road shows”; and (ix) all expenses and application fees related to the listing of the Shares on the Exchange. It is, however, understood that except as provided in this Section 11 or Section 7 hereof, the Underwriters shall pay all of their own costs and expenses, including, without limitation, the fees and disbursements of their counsel.

 

30


(b) If (i) this Agreement is terminated pursuant to Sections 9(i) or (ii), (ii) the Company for any reason fails to tender the Shares for delivery to the Underwriters (other than by reason of a default by any Underwriter) or (iii) the Underwriters decline to purchase the Shares for any reason permitted under this Agreement, the Company agrees to reimburse the Underwriters for all reasonable and documented out-of-pocket costs and expenses (including the reasonable and documented fees and expenses of their counsel) reasonably incurred by the Underwriters in connection with this Agreement and the offering contemplated hereby. For the avoidance of doubt, it is understood that the Company shall not pay or reimburse any costs, fees or expenses incurred by any Underwriter that defaults on its obligations to purchase the Shares.

12. Persons Entitled to Benefit of Agreement. This Agreement shall inure to the benefit of and be binding upon the parties hereto and their respective successors and the officers and directors and any controlling persons referred to herein, and the affiliates of each Underwriter referred to in Section 7 hereof. Nothing in this Agreement is intended or shall be construed to give any other person any legal or equitable right, remedy or claim under or in respect of this Agreement or any provision contained herein. No purchaser of Shares from any Underwriter shall be deemed to be a successor merely by reason of such purchase.

13. Survival. The respective indemnities, rights of contribution, representations, warranties and agreements of the Company and the Underwriters contained in this Agreement or made by or on behalf of the Company or the Underwriters pursuant to this Agreement or any certificate delivered pursuant hereto shall survive the delivery of and payment for the Shares and shall remain in full force and effect, regardless of any termination of this Agreement or any investigation made by or on behalf of the Company or the Underwriters or the directors, officers, controlling persons or affiliates referred to in Section 7 hereof.

14. Certain Defined Terms. For purposes of this Agreement, (a) except where otherwise expressly provided, the term “affiliate” has the meaning set forth in Rule 405 under the Securities Act; (b) the term “business day” means any day other than a day on which banks are permitted or required to be closed in New York City; and (c) the term “subsidiary” has the meaning set forth in Rule 405 under the Securities Act.

15. Compliance with USA Patriot Act. In accordance with the requirements of the USA Patriot Act (Title III of Pub. L. 107-56 (signed into law October 26, 2001)), the Underwriters are required to obtain, verify and record information that identifies their respective clients, including the Company, which information may include the name and address of their respective clients, as well as other information that will allow the Underwriters to properly identify their respective clients.

16. Miscellaneous.

(a) Notices. All notices and other communications hereunder shall be in writing and shall be deemed to have been duly given if mailed or transmitted and confirmed by any standard form of telecommunication. Notices to the Underwriters shall be given to the Representatives c/o Goldman Sachs & Co. LLC, 200 West Street, New York, New York 10282-2198, Attention: Control Room; J.P. Morgan Securities LLC, 383 Madison Avenue, New York, New York 10179 (fax: (212) 622-8358); Attention: Equity Syndicate Desk; BofA Securities, Inc., One Bryant

 

31


Park, New York, NY 10036, Email: dg.ecm_execution_services@bofa.com, Attention: Syndicate Department, with a copy to: Email: dg.ecm_legal@bofa.com, Attention: ECM Legal. Notices to the Company shall be given to it at Venture Global, Inc. 1001 19th Street North, Suite 1500 Arlington, VA 22209 Attention: Chief Financial Officer, Email: jthayer@vglng.com and General Counsel, Email: klarson@venturegloballng.com.

(b) Governing Law. This Agreement and any claim, controversy or dispute arising under or related to this Agreement shall be governed by and construed in accordance with the laws of the State of New York.

(c) Submission to Jurisdiction. Any legal suit, action or proceeding arising out of or based upon this Agreement or the transactions contemplated hereby (a “Related Proceeding”) may be instituted in the federal courts of the United States of America located in the City and County of New York or the courts of the State of New York in each case located in the City and County of New York (collectively, the “Specified Courts”), and each party irrevocably submits to the exclusive jurisdiction (except for suits, actions, or proceedings instituted in regard to the enforcement of a judgment of any Specified Court in a Related Proceeding (a “Related Judgment”), as to which such jurisdiction is non-exclusive) of the Specified Courts in any Related Proceeding. Service of any process, summons, notice or document by mail to such party’s address set forth above shall be effective service of process for any Related Proceeding brought in any Specified Court. The parties irrevocably and unconditionally waive any objection which they may now or hereafter have to the laying of venue of any Related Proceeding in the Specified Courts and irrevocably and unconditionally waive and agree not to plead or claim in any Specified Court that any Related Proceeding brought in any Specified Court has been brought in an inconvenient forum. The parties agree that final judgment in any such Related Proceeding brought in such Specified Courts shall be conclusive and binding upon the parties and may be enforced in any court to the jurisdiction of which the parties are subject by a suit upon such judgment.

(f) WAIVER OF JURY TRIAL. EACH OF THE PARTIES HERETO HEREBY WAIVES ANY RIGHT TO TRIAL BY JURY IN ANY SUIT OR PROCEEDING ARISING OUT OF OR RELATING TO THIS AGREEMENT.

(g) Recognition of the U.S. Special Resolution Regimes.

(i) In the event that any Underwriter that is a Covered Entity becomes subject to a proceeding under a U.S. Special Resolution Regime, the transfer from such Underwriter of this Agreement, and any interest and obligation in or under this Agreement, will be effective to the same extent as the transfer would be effective under the U.S. Special Resolution Regime if this Agreement, and any such interest and obligation, were governed by the laws of the United States or a state of the United States.

(ii) In the event that any Underwriter that is a Covered Entity or a BHC Act Affiliate of such Underwriter becomes subject to a proceeding under a U.S. Special Resolution Regime, Default Rights under this Agreement that may be exercised against such Underwriter are permitted to be exercised to no greater extent than such Default Rights could be exercised under the U.S. Special Resolution Regime if this Agreement were governed by the laws of the United States or a state of the United States.

 

32


As used in this Section 16(g):

“BHC Act Affiliate” has the meaning assigned to the term “affiliate” in, and shall be interpreted in accordance with, 12 U.S.C. § 1841(k).

“Covered Entity” means any of the following:

(i) a “covered entity” as that term is defined in, and interpreted in accordance with, 12 C.F.R. § 252.82(b);

(ii) a “covered bank” as that term is defined in, and interpreted in accordance with, 12 C.F.R. § 47.3(b); or

(iii) a “covered FSI” as that term is defined in, and interpreted in accordance with, 12 C.F.R. § 382.2(b).

“Default Right” has the meaning assigned to that term in, and shall be interpreted in accordance with, 12 C.F.R. §§ 252.81, 47.2 or 382.1, as applicable.

“U.S. Special Resolution Regime” means each of (i) the Federal Deposit Insurance Act and the regulations promulgated thereunder and (ii) Title II of the Dodd-Frank Wall Street Reform and Consumer Protection Act and the regulations promulgated thereunder.

(h) Counterparts. This Agreement may be signed in counterparts (which may include counterparts delivered by any standard form of telecommunication), each of which shall be an original and all of which together shall constitute one and the same instrument. The parties agree to electronic contracting and signatures with respect to this Agreement. Delivery of an electronic signature to, or a signed copy of, this Agreement by facsimile, email or other electronic transmission shall be fully binding on the parties to the same extent as the delivery of the signed originals and shall be admissible into evidence for all purposes. The words “execution,” “execute”, “signed,” “signature,” and words of like import in or related to any document to be signed in connection with this Agreement and the transactions contemplated hereby shall be deemed to include electronic signatures, the electronic matching of assignment terms and contract formations on electronic platforms approved by the parties hereto, or the keeping of records in electronic form, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any applicable law, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

 

33


(i) Amendments or Waivers. No amendment or waiver of any provision of this Agreement, nor any consent or approval to any departure therefrom, shall in any event be effective unless the same shall be in writing and signed by the parties hereto.

(j) Headings. The headings herein are included for convenience of reference only and are not intended to be part of, or to affect the meaning or interpretation of, this Agreement.

 

34


If the foregoing is in accordance with your understanding, please indicate your acceptance of this Agreement by signing in the space provided below.

 

Very truly yours,

 

VENTURE GLOBAL, INC.

By:    
  Name:
  Title:

 

Accepted: As of the date first written above

 

GOLDMAN SACHS & CO. LLC

 

For itself and on behalf of the
several Underwriters listed
in Schedule 1 hereto.
By:    
  Authorized Signatory

 

J.P. MORGAN SECURITIES LLC

 

For itself and on behalf of the

several Underwriters listed

in Schedule 1 hereto.

By:    
  Authorized Signatory

 

BOFA SECURITIES, INC.

 

For itself and on behalf of the

several Underwriters listed

in Schedule 1 hereto.

By:    
  Authorized Signatory

 

 

35


Schedule 1

 

Underwriter

   Number of Shares  

Goldman Sachs & Co. LLC

  

J.P. Morgan Securities LLC

  

BofA Securities, Inc.

  

ING Financial Markets LLC

  

RBC Capital Markets, LLC

  

Scotia Capital (USA) Inc.

  

Mizuho Securities USA LLC

  

Santander US Capital Markets LLC

  

SMBC Nikko Securities America, Inc.

  

MUFG Securities Americas Inc.

  

BBVA Securities Inc.

  
  

 

 

 

Total

  
  

 

 

 

 

36


Annex A

 

  a.

Issuer Free Writing Prospectus Included in the Pricing Disclosure Package

[None]

 

  b.

Pricing Information Provided Orally by Underwriters

Number of Underwritten Shares: [•]

Number of Option Shares: [•]

Public Offering Price: $[•] per Share

 

37


Annex B

Written Testing-the-Waters Communications

1. Testing the Waters Presentation dated November 12, 2024

 

38


Annex C

Venture Global, Inc.

Pricing Term Sheet

None.

 

39


Exhibit A

Testing the waters authorization (to be delivered by the issuer to Goldman, J.P. Morgan and BofA in email or letter form)

In reliance on Rule 163B under the Securities Act of 1933, as amended (the “Act”), Venture Global, Inc. (the “Issuer”) hereby authorizes Goldman Sachs & Co. LLC (“Goldman”) and its affiliates and their respective employees, J.P. Morgan Securities LLC (“J.P. Morgan”) and its affiliates and their respective employees, and BofA Securities, Inc. (“BofA”) and its affiliates and their respective employees, to engage on behalf of the Issuer in oral and written communications with potential investors that are reasonably believed to be “qualified institutional buyers”, as defined in Rule 144A under the Act, or institutions that are “accredited investors”, within the meaning of Rule 501(a)(1), (a)(2), (a)(3), (a)(7) or (a)(8) under the Act, to determine whether such investors might have an interest in the Issuer’s contemplated initial public offering (“Testing-the-Waters Communications”). A “Written Testing-the Waters Communication” means any Testing-the-Waters Communication that is a written communication within the meaning of Rule 405 under the Act. Each of Goldman, J.P. Morgan and BofA, individually and not jointly, agrees that it shall not distribute any Written Testing-the-Waters Communication that has not been approved by the Issuer.

If at any time following the distribution of any Written Testing-the-Waters Communication there occurs an event or development as a result of which such Written Testing-the-Waters Communication included or would include an untrue statement of a material fact or omitted or would omit to state a material fact necessary in order to make the statements therein, in the light of the circumstances existing at that subsequent time, not misleading, the Issuer will promptly notify Goldman, J.P. Morgan and BofA and will promptly amend or supplement, at its own expense, such Written Testing-the-Waters Communication to eliminate or correct such untrue statement or omission.

Nothing in this authorization is intended to limit or otherwise affect the ability of Goldman and its affiliates and their respective employees, J.P. Morgan and its affiliates and their respective employees, and BofA and its affiliates and their respective employees, to engage in communications in which they could otherwise lawfully engage in the absence of this authorization, including, without limitation, any written communication containing only one or more of the statements specified under Rule 134(a) under the Act. This authorization shall remain in effect until the Issuer has provided to Goldman, J.P. Morgan and BofA a written notice revoking this authorization. All notices as described herein shall be sent by email to the attention of, for Goldman, [•] at [•], with copies to [•];for J.P. Morgan, [•] at [•], with copies to [•]; and for BofA, [•] at [•], with copies to [•].

 

40


Exhibit B

Form of Waiver of Lock-up

GOLDMAN SACHS & CO. LLC

J.P. MORGAN SECURITIES LLC

BOFA SECURITIES, INC.

Venture Global, Inc.

Public Offering of Common Stock

, 20__

[Name and Address of

Officer or Director

Requesting Waiver]

Dear Mr./Ms. [Name]:

This letter is being delivered to you in connection with the offering by Venture Global, Inc. (the “Company”) of     shares of Class A common stock, $0.01 par value (the “Common Stock”), of the Company and the lock-up letter dated       , 20[•] (the “Lock-up Letter”), executed by you in connection with such offering, and your request for a [waiver] [release] dated      , 20, with respect to     shares of Common Stock (the “Shares”).

 

The Representatives hereby agree to [waive] [release] the transfer restrictions set forth in the Lock-up Letter, but only with respect to the Shares, effective      , 20; provided, however, that such [waiver] [release] is conditioned on the Company announcing the impending [waiver] [release] by press release through a major news service at least two business days before effectiveness of such [waiver] [release]. This letter will serve as notice to the Company of the impending [waiver] [release].

Except as expressly [waived] [released] hereby, the Lock-up Letter shall remain in full force and effect.

 

Yours very truly,

 

[Signature]

 

cc:

Company

 

41


Exhibit C

Form of Press Release

Venture Global, Inc.

[Date]

Venture Global, Inc. (“Company”) announced today that Goldman Sachs & Co. LLC, J.P. Morgan Securities LLC and BofA Securities, Inc., the lead book-running managers in the Company’s recent public sale of    shares of Class A common stock, are [waiving] [releasing] a lock-up restriction with respect to shares of the Company’s Class A common stock held by [certain officers or directors] [an officer or director] of the Company. The [waiver] [release] will take effect on       , 20, and the shares may be sold on or after such date.

This press release is not an offer for sale of the securities in the United States or in any other jurisdiction where such offer is prohibited, and such securities may not be offered or sold in the United States absent registration or an exemption from registration under the United States Securities Act of 1933, as amended.

 

42


Exhibit D

LOCK-UP AGREEMENT

[•], 20[•]

BOFA SECURITIES, INC.

GOLDMAN SACHS & CO. LLC

J.P. MORGAN SECURITIES LLC

As Representatives of

the several Underwriters listed in

Schedule 1 to the Underwriting

Agreement referred to below

c/o BofA Securities, Inc.

One Bryant Park

New York, New York 10036

c/o Goldman Sachs & Co. LLC

200 West Street

New York, NY 10282-2198

c/o J.P. Morgan Securities LLC

383 Madison Avenue

New York, NY 10179

Re:  Venture Global, Inc. — Public Offering

Ladies and Gentlemen:

The undersigned understands that you, as Representatives of the several Underwriters, propose to enter into an underwriting agreement (the “Underwriting Agreement”) with Venture Global, Inc., a Delaware corporation (the “Company”), providing for the public offering (the “Public Offering”) by the several Underwriters named in Schedule 1 to the Underwriting Agreement (the “Underwriters”), of shares of Class A common stock, par value $0.01 per share (the “Class A Common Stock”), of the Company (the “Securities”). Capitalized terms used herein and not otherwise defined shall have the meanings set forth in the Underwriting Agreement.

In consideration of the Underwriters’ agreement to purchase and make the Public Offering of the Securities, and for other good and valuable consideration receipt of which is hereby acknowledged, the undersigned hereby agrees that, without the prior written consent of BofA Securities, Inc., Goldman Sachs & Co. LLC and J.P. Morgan Securities LLC on behalf of the Underwriters (the “Representatives”), the undersigned will not, and will not cause any direct or indirect affiliate to, during the period beginning on the date of this letter agreement (this “Letter Agreement”) and ending at the close of business 180 days after the date of the final prospectus relating to the Public Offering (the “Prospectus”) (such period, the “Restricted

 

43


Period”), (1) offer, pledge, sell, contract to sell, sell any option or contract to purchase, purchase any option or contract to sell, grant any option, right or warrant to purchase, lend, or otherwise transfer or dispose of, directly or indirectly, any shares of Class A Common Stock or any securities convertible into or exercisable or exchangeable for Class A Common Stock (including without limitation, Class A Common Stock or such other securities which may be deemed to be beneficially owned by the undersigned in accordance with the rules and regulations of the Securities and Exchange Commission (the “SEC”) and securities which may be issued upon exercise of a stock option or warrant) (collectively with Class A Common Stock, “Lock-Up Securities”), (2) enter into any hedging, swap or other agreement or transaction that transfers, in whole or in part, any of the economic consequences of ownership of the Lock-Up Securities, whether any such transaction described in clause (1) or (2) above is to be settled by delivery of Lock-Up Securities, in cash or otherwise, (3) make any demand for or exercise any right with respect to the registration of any Lock-Up Securities; provided that, to the extent any Holder (as defined below) has demand and/or piggyback registration rights to require registration under the Securities Act with respect to Holder’s Lock-Up Securities, the foregoing shall not prohibit such Holder from notifying the Company privately that it will be exercising such demand and/or piggyback registration rights following the expiration of the Restricted Period and undertaking any non-public preparations related thereto; provided, further, that (i) no transfers of Holder’s Lock-Up Securities registered pursuant to the exercise of any such right shall be made, and no registration statement shall be publicly filed under the Securities Act with respect to any of the Holder’s Lock-Up Securities during the Restricted Period and (ii) for the avoidance of doubt, no press release shall be issued in connection with the registration by the Company of any such securities (including in connection with the confidential submission of any registration statement with the SEC) during the Restricted Period, or (4) publicly disclose the intention to do any of the foregoing. The undersigned acknowledges and agrees that the foregoing precludes the undersigned from engaging in any hedging or other transactions or arrangements (including, without limitation, any short sale or the purchase or sale of, or entry into, any put or call option, or combination thereof, forward, swap or any other derivative transaction or instrument, however described or defined) designed or intended, or which could reasonably be expected to lead to or result in, a sale or disposition or transfer (whether by the undersigned or any other person) of any economic consequences of ownership, in whole or in part, directly or indirectly, of any Lock-Up Securities, whether any such transaction or arrangement (or instrument provided for thereunder) would be settled by delivery of Lock-Up Securities, in cash or otherwise. The undersigned further confirms that it has furnished the Representatives with the details of any transaction the undersigned, or any of its affiliates, is a party to as of the date hereof, which transaction would have been restricted by this Letter Agreement if it had been entered into by the undersigned during the Restricted Period.

Notwithstanding the foregoing, the undersigned may:

(a) transfer, distribute, or dispose of (as the case may be) the undersigned’s Lock-Up Securities:

(i) as a bona fide gift or gifts, or for bona fide estate planning purposes,

(ii) by will, other testamentary document or intestacy,

 

44


(iii) to any trust for the direct or indirect benefit of the undersigned or the immediate family of the undersigned, or if the Lock-Up Securities are held by a trust, to a trustor or beneficiary of the trust or to the estate of a beneficiary of such trust (for purposes of this Letter Agreement, “immediate family” shall mean any relationship by blood, current or former marriage, domestic partnership or adoption, not more remote than first cousin),

(iv) to a corporation, partnership, limited liability company or other entity of which the undersigned and/or the immediate family of the undersigned are the legal and beneficial owner of all of the outstanding equity securities or similar interests,

(v) to a nominee or custodian of a person or entity to whom a transfer, distribution or disposition would be permissible under clauses (i) through (iv) above,

(vi) if the Lock-Up Securities are held by a corporation, partnership, limited liability company, trust or other business entity (the “Holder”), (A) to another corporation, partnership, limited liability company, trust or other business entity that is an affiliate (as defined in Rule 405 promulgated under the Securities Act of 1933, as amended) of the Holder, or to any investment fund or other entity controlling, controlled by, managing or managed by or under common control with the Holder or affiliates of the Holder (including, for the avoidance of doubt, where the Holder’s Lock-Up Securities are held by a partnership, to its general partner or a successor partnership or fund, or any other funds managed by such partnership), or (B) as part of a distribution to members, partners, shareholders or other equityholders of the Holder,

(vii) by operation of law, such as pursuant to a qualified domestic order, divorce settlement, divorce decree, separation agreement or other court order,

(viii) to the Company from a current or former employee of the Company upon death, disability or termination of employment, in each case, of such employee,

(ix) as part of a sale of the undersigned’s Lock-Up Securities acquired in the Public Offering (except as otherwise provided in this Letter Agreement) or in open market transactions after the effective date of the registration statement for the Public Offering,

(x) to the Company in connection with the vesting, settlement, or exercise of restricted stock units, options, warrants or other equity or equity-based awards or rights with respect to or to purchase shares of Class A Common Stock (“Equity-Based Grants”), including for the payment of exercise price and tax, remittance and other obligations due as a result of the vesting, settlement, or exercise of such Equity-Based Grants (in each case, whether by way of “net” or “cashless” exercise, “net settlement” or otherwise), provided that any such shares of Class A Common Stock received upon such exercise, vesting or settlement not used for the purpose of payment of exercise price and/or tax, remittance and other obligations due as a result of the vesting, settlement, or exercise of such Equity-Based Grants shall be subject to the terms of this Letter Agreement, and provided further that any such Equity-Based Grants are held by the undersigned pursuant to an agreement or equity awards granted under a stock incentive plan or other equity award plan, each such agreement or plan which is described in the Registration Statement, the Pricing Disclosure Package and the Prospectus, or

 

 

45


(xi) pursuant to a bona fide third-party tender offer, merger, consolidation or other similar transaction that is approved by the Board of Directors of the Company and made to all holders of the Company’s capital stock involving a Change of Control (as defined below) of the Company (for purposes hereof, “Change of Control” shall mean the transfer (whether by tender offer, merger, consolidation or other similar transaction), in one transaction or a series of related transactions, to a person or group of affiliated persons, of shares of capital stock if, after such transfer, such person or group of affiliated persons would hold at least a majority of the outstanding voting securities of the Company (or the surviving entity)); provided that in the event that such tender offer, merger, consolidation or other similar transaction is not completed, the undersigned’s Lock-Up Securities shall remain subject to the provisions of this Letter Agreement; provided that (A) in the case of any transfer, distribution or other disposition pursuant to clauses (a)(i), (ii), (iii), (iv), (v), (vi) and (vii), such transfer shall not involve a disposition for value and each donee, devisee, transferee or distributee shall execute and deliver to the Representatives a lock-up letter in the form of this Letter Agreement, (B) in the case of any transfer, distribution or other disposition pursuant to clauses (a)(i), (ii), (iii), (iv), (v), (vi) and (ix), no filing by any party (donor, donee, devisee, transferor, transferee, distributer or distributee) under the Securities Exchange Act of 1934, as amended (the “Exchange Act”), or other public announcement shall be required or shall be made voluntarily in connection with such transfer, distribution or other disposition (other than (x) a required filing on a Form 5 made after the expiration of the Restricted Period or (y) a required filing under Section 16(a) of the Exchange Act or on a Schedule 13F or 13G that discloses therein that such transfer, distribution or other disposition is a bona fide gift or otherwise a disposition for no value (and if such recipient of securities is a person, trust or entity that would report a corresponding acquisition of such securities on the undersigned’s Form 4, and such acquisition is entitled to be reported on a Form 5, such acquisition may be voluntarily reported on such Form 4) and (C) in the case of any transfer, distribution or other disposition pursuant to clause (a)(vii), (viii) and (x) it shall be a condition to such transfer that no public filing, report or announcement shall be voluntarily made and if any filing under Section 16(a) of the Exchange Act or on a Schedule 13F or 13G, or other public filing, report or announcement reporting a reduction in beneficial ownership of shares of Class A Common Stock in connection with such transfer, distribution or other disposition shall be legally required during the Restricted Period, such filing, report or announcement shall clearly indicate in the footnotes thereto the nature and conditions of such transfer, or

(b) exercise outstanding options, settle restricted stock units or other equity awards or exercise warrants pursuant to plans described in the Registration Statement, the Pricing Disclosure Package and the Prospectus; provided that any Lock-up Securities received upon such exercise, vesting or settlement shall be subject to the terms of this Letter Agreement;

(c) convert outstanding preferred stock, warrants to acquire preferred stock or convertible securities into Lock-up Securities or warrants to acquire Lock-up Securities; provided that any such shares of Class A Common Stock or warrants received upon such conversion shall be subject to the terms of this Letter Agreement;

 

46


(d) establish trading plans pursuant to Rule 10b5-1 under the Exchange Act for the transfer of shares of Lock-Up Securities; provided that such plans do not provide for the transfer of Lock-Up Securities during the Restricted Period; and provided further that no filing by any person under the Exchange Act or other public announcement shall be voluntarily made and that any public announcement or filing under the Exchange Act required to be made by any person in connection with the establishment of such plan during the Restricted Period shall include a statement that the undersigned is not permitted to transfer, sell or otherwise dispose of securities under such plan during the Restricted Period in contravention of this Letter Agreement); and

(e) convert, reclassify or exchange shares of Class A Common Stock into shares of Class B common stock, par value $0.01 per share (“Class B Common Stock”), of the Company as described in the Registration Statement, the Pricing Disclosure Package and the Prospectus, or convert, reclassify or exchange shares of Class B Common Stock into shares of Class A Common Stock pursuant to the terms of Class B Common Stock; provided that any Lock-up Securities received upon such conversion, reclassification or exchange shall be subject to the terms of this Letter Agreement.

If the undersigned is not a natural person, the undersigned represents and warrants that no single natural person, entity or “group” (within the meaning of Section 13(d)(3) of the Exchange Act) beneficially owns, directly or indirectly, 50% or more of the common equity interests, or 50% or more of the voting power, in the undersigned.

If the undersigned is an officer or director of the Company, the undersigned further agrees that the foregoing provisions shall be equally applicable to any Company-directed Securities the undersigned may purchase in the Public Offering.

If the undersigned is an officer or director of the Company, (i) the Representatives, on behalf of the Underwriters, agree that, at least three business days before the effective date of any release or waiver of the foregoing restrictions in connection with a transfer of shares of Lock-Up Securities, the Representatives, on behalf of the Underwriters, will notify the Company of the impending release or waiver, and (ii) the Company has agreed in the Underwriting Agreement to announce the impending release or waiver through a major news service at least two business days before the effective date of the release or waiver. Any release or waiver granted by the Representatives on behalf of the Underwriters hereunder to any such officer or director shall only be effective two business days after the publication date of such announcement. The provisions of this paragraph will not apply if (a) the release or waiver is effected solely to permit a transfer not for consideration or that is to an immediate family member as defined in FINRA Rule 5130(i)(5) and (b) the transferee has agreed in writing to be bound by the same terms described in this letter to the extent and for the duration that such terms remain in effect at the time of the transfer.

In furtherance of the foregoing, the Company, and any duly appointed transfer agent for the registration or transfer of the securities described herein, are hereby authorized to decline to make any transfer of securities if such transfer would constitute a violation or breach of this Letter Agreement.

The undersigned hereby represents and warrants that the undersigned has full power and authority to enter into this Letter Agreement. All authority herein conferred or agreed to be conferred and any obligations of the undersigned shall be binding upon the successors, assigns, heirs or personal representatives of the undersigned.

 

47


The undersigned acknowledges and agrees that the Underwriters have not provided any recommendation or investment advice nor have the Underwriters solicited any action from the undersigned with respect to the Public Offering of the Securities and the undersigned has consulted their own legal, accounting, financial, regulatory and tax advisors to the extent deemed appropriate. The undersigned further acknowledges and agrees that, although the Representatives may be required or choose to provide certain Regulation Best Interest and Form CRS disclosures to you in connection with the Public Offering, the Representatives and the other Underwriters are not making a recommendation to you to enter into this Letter Agreement, and nothing set forth in such disclosures is intended to suggest that the Representatives or any Underwriter is making such a recommendation.

The undersigned understands that, if (i) the Underwriting Agreement does not become effective by February 13, 2025, (ii) the Underwriting Agreement (other than the provisions thereof which survive termination) shall terminate or be terminated prior to payment for and delivery of the Class A Common Stock to be sold thereunder, (iii) prior to the execution of the Underwriting Agreement, either the Company, on the one hand, or the Representatives, on the other hand, notifies the other in writing that it does not intend to proceed with the Public Offering, or (iv) the registration statement filed with the SEC in connection with the Public Offering is withdrawn, the undersigned shall be automatically released from all obligations under this Letter Agreement. The undersigned understands that the Underwriters are entering into the Underwriting Agreement and proceeding with the Public Offering in reliance upon this Letter Agreement.

This Letter Agreement and any claim, controversy or dispute arising under or related to this Letter Agreement shall be governed by and construed in accordance with the laws of the State of New York.

This Letter Agreement may be delivered via facsimile, electronic mail (including pdf or any electronic signature complying with the U.S. federal ESIGN Act of 2000, e.g., www.docusign.com or www.echosign.com) or other transmission method and any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

 

Very truly yours,

[NAME]

By:

   
 

Name:

 

Title:

 

48

Exhibit 3.1

FORM OF SECOND AMENDED AND RESTATED

CERTIFICATE OF INCORPORATION

OF

VENTURE GLOBAL, INC.

Venture Global, Inc. (the “Corporation”), a corporation organized under the laws of Delaware, hereby certifies as follows:

A. The name of the corporation is Venture Global, Inc. The original name of the Corporation was Venture Global Holdings, Inc. On September 19, 2023, the Corporation filed the original Certificate of Incorporation with the Secretary of State of the State of Delaware. On September 25, 2023, the Corporation filed an Amended and Restated Certificate of Incorporation with the Secretary of State of the State of Delaware. On January 17, 2024, the Corporation filed a Certificate of Amendment of the Amended and Restated Certificate of Incorporation with the Secretary of State of the State of Delaware changing its name to Venture Global, Inc.

B. This Second Amended and Restated Certificate of Incorporation (this “Certificate of Incorporation”) was duly adopted in accordance with Sections 242 and 245 of the General Corporation Law of the State of Delaware and has been duly approved by the written consent of the Corporation’s stockholders in accordance with Section 228 of the General Corporation Law of the State of Delaware.

C. The text of the Certificate of Incorporation of the Corporation is hereby amended and restated in its entirety as follows:


ARTICLE I

NAME

The name of the corporation is Venture Global, Inc. (the “Corporation”).

ARTICLE II

REGISTERED OFFICE AND AGENT

The registered agent of the Corporation is The Corporation Trust Company. The registered office of the Corporation in the State of Delaware is to be located at 1209 Orange Street, City of Wilmington, County of New Castle, Delaware 19801.

ARTICLE III

PURPOSE AND POWERS

The purpose of the Corporation is to engage in any lawful act or activity for which corporations may be organized under the General Corporation Law of the State of Delaware as the same exists or may hereafter be amended (the “DGCL”).

ARTICLE IV

CAPITAL STOCK

A. Authorized Shares. The total number of shares of stock which the Corporation shall have authority to issue is [•] consisting of (a) [•] shares of Class A common stock with a par value of $0.01 per share (“Class A Common Stock”), and [•] shares of Class B common stock with a par value of $0.01 per share (“Class B Common Stock” and, together with Class A Common Stock, “Common Stock”) and (b) [•] shares of preferred stock with a par value of $0.01 per share (“Preferred Stock”).

Upon the Effective Time, each share of Class A Common Stock issued and outstanding or held in treasury immediately prior to the Effective Time shall be reclassified as, and shall be converted into [•] shares of fully paid and non-assessable Class A Common Stock (the “Stock Split”), without any action by the holder thereof.

Each share of Class A Common Stock held of record by VGP or any VGP Entity immediately after the effectiveness of the Stock Split shall be converted into one fully paid and non-assessable share of Class B Common Stock, without any action by the holder thereof or the Corporation, and each other share of Class A Common Stock shall remain as such.

B. Common Stock.

The rights, powers, preferences, privileges, restrictions and other matters relating to Common Stock are as follows:

 

  (a)

Identical Rights.

 

  (1)

Except as otherwise provided in this Certificate of Incorporation or required by applicable law, shares of Class A Common Stock and Class B Common Stock shall have the same rights and powers, share ratably and be identical in all respects as to all matters, including as to dividends and distributions, and any liquidation, dissolution or winding up of the Corporation.

 

1


  (2)

If the Corporation in any manner reclassifies, subdivides or combines the outstanding shares of Class A Common Stock or Class B Common Stock, then the outstanding shares of all Common Stock will concurrently therewith be proportionately reclassified, subdivided or combined in a manner that maintains the same proportionate equity ownership and relative voting rights between the outstanding shares of Class A Common Stock and the outstanding shares of Class B Common Stock on the record date for such reclassification, subdivision or combination; provided, however, that, notwithstanding anything in this Certificate of Incorporation to the contrary, shares of one such class may be reclassified, subdivided or combined in a different or disproportionate manner if such reclassification, subdivision or combination is approved by the affirmative vote of the holders of a majority of the voting power of the outstanding shares of Class A Common Stock and Class B Common Stock, each voting as a separate class.

 

  (b)

Voting.

 

  (1)

(i) Each holder of Class A Common Stock, as such, shall be entitled to one vote for each share of Class A Common Stock held of record by such holder, and (ii) each holder of Class B Common Stock, as such, shall be entitled to ten votes for each share of Class B Common Stock held of record by such holder, in each case, on all matters on which stockholders generally are entitled to vote; provided, however, that, except as otherwise required by law, holders of Common Stock, as such, shall not be entitled to vote on any amendment to this Certificate of Incorporation (including any certificate of designations relating to any series of Preferred Stock) that relates solely to the terms of one or more outstanding series of Preferred Stock if the holders of such series are entitled, either separately or together with the holders of one or more other such series, to vote thereon pursuant to this Certificate of Incorporation (including any certificate of designations relating to any series of Preferred Stock) or pursuant to the DGCL.

 

  (2)

The number of authorized shares of any class of capital stock of the Corporation may be increased or decreased by the affirmative vote of the holders of a majority of the voting power of all then-outstanding shares of capital stock of the Corporation entitled to vote thereon, voting as a single class, irrespective of the provisions of Section 242(b)(2) of the DGCL (in addition to any vote of the holders of one or more series of Preferred Stock that may be required by the terms of any certificate of designations). Notwithstanding the immediately preceding sentence, the number of

 

2


  authorized shares of any particular class may not be decreased below the number of shares of such class then outstanding, plus in the case of Class A Common Stock, the number of shares of Class A Common Stock issuable in connection with the exercise of outstanding options, warrants, exchange rights, conversion rights or similar rights for Class A Common Stock. For the avoidance of doubt, subject to the rights of the holders of any outstanding series of Preferred Stock, Section 242(d) of the DGCL shall apply to amendments to this Certificate of Incorporation.

 

  (3)

Except as required by law or in this Certificate of Incorporation, the holders of Class A Common Stock and Class B Common Stock shall vote together as a single class and not as separate classes on any matter submitted to a vote of, or required to be voted on by, holders of Common Stock.

 

  (4)

There shall be no cumulative voting.

 

  (c)

Dividend Rights.

 

  (1)

Subject to the prior rights of holders of any classes and series of stock at the time outstanding having prior rights as to dividends, the holders of Common Stock shall be entitled to receive, when, as and if declared by the Board of Directors, out of any assets of the Corporation legally available therefor, such dividends as may be declared from time to time by the Board of Directors.

 

  (2)

Any dividends paid to the holders of shares of Common Stock shall be paid pro rata to the holders of Common Stock ratably on an equal priority, pari passu basis among the holders of Common Stock as a single class; provided, however, that (i) dividends payable in shares of Class A Common Stock (or rights to acquire, or securities convertible into or exchangeable for, such shares, as the case may be) may be declared and paid to the holders of Class A Common Stock without the same dividend being declared and paid to the holders of Class B Common Stock if, and only if, a dividend payable in shares of Class B Common Stock (or rights to acquire, or securities convertible into or exchangeable for, such shares, as the case may be), are declared and paid to the holders of Class B Common Stock at the same rate and with the same record date and payment date, (ii) dividends payable in shares of Class B Common Stock (or rights to acquire, or securities convertible into or exchangeable for, such shares, as the case may be) may be declared and paid to the holders of Class B Common Stock without the same dividend being declared and paid to the holders of Class A Common Stock if, and only if, a dividend payable in shares of Class A Common Stock (or rights to acquire, or securities convertible into or exchangeable for, such shares, as the case may be) are declared and paid to the holders of Class A Common Stock at the same rate and with the same record date and payment date and (iii)

 

3


  dividends payable in shares of any other class or series of securities of the Corporation or any other Person (or rights to acquire, or securities convertible into or exchangeable for, such shares, as the case may be) may be declared and paid to the holders of shares of Common Stock on a different or disproportionate basis if the only differences are in voting power and such other differences that are substantially equivalent (as determined by the Board of Directors) to the relative designations, preferences, qualifications, privileges, limitations, restrictions and rights. Furthermore, the Board of Directors may pay a different or disproportionate dividend per share of Class A Common Stock or Class B Common Stock (whether in the amount of such dividend payable per share, the form in which such dividend is payable, the timing of the payment, or otherwise) that would otherwise be prohibited by the immediately preceding sentence, if such different or disproportionate dividend is approved by the affirmative vote of the holders of a majority of the voting power of the outstanding shares of Class A Common Stock and Class B Common Stock, each voting as a separate class.

 

  (d)

Liquidation. In the event of a Liquidation Event, subject to the rights of any Preferred Stock that may then be outstanding, the assets of the Corporation legally available for distribution to stockholders shall be distributed to the holders of Common Stock ratably on an equal priority, pari passu basis among the holders of Common Stock as a single class, unless different or disproportionate treatment of the shares of each such class is approved by the affirmative vote of the holders of a majority of the voting power of the outstanding shares of Class A Common Stock and Class B Common Stock, each voting as a separate class.

 

  (e)

Merger, Consolidation or Other Transaction.

 

  (1)

In the case of any distribution or payment in respect of the shares of Common Stock, or any payment or delivery of any consideration into which such shares are converted or exchanged, in each case upon any merger, consolidation or conversion of the Corporation with or into any other entity, or any other transaction having an effect on stockholders substantially similar to that resulting from a merger, consolidation or conversion of the Corporation with or into any other entity, such distribution, payment, or consideration that the holders of shares of Common Stock have the right to receive, or the right to elect to receive, shall be made ratably on an equal priority, pari passu basis among the holders of Common Stock as a single class; provided, however, that any or all of such shares of any or all of such classes may (but shall not be required to) receive, or have the right to elect to receive, different or disproportionate consideration in connection with any such merger, consolidation, conversion or other transaction if (x) in the case of any such distribution, payment or consideration in the form of securities, the only differences are in voting power and such other differences that are substantially equivalent (as determined by the Board of Directors) to the

 

4


  relative designations, preferences, qualifications, privileges, limitations, restrictions and rights of Class A Common Stock and Class B Common Stock or (y) such merger, consolidation, conversion or other transaction is approved by the affirmative vote of the holders of a majority of the voting power of the outstanding shares of Class A Common Stock and Class B Common Stock, each voting as a separate class.

 

  (2)

For the avoidance of doubt, any distribution, payment or consideration for purposes of this Article IV, Section B(e) shall not be deemed to include (i) any amount or consideration to be paid to or received by a holder of Common Stock pursuant to any indemnification, employment, consulting, severance or similar services arrangement, whether or not entered into in connection with a transaction described in Article IV, Section B(e)(1), or (ii) a negotiated agreement between a holder of Common Stock with any counterparty (or Affiliate thereof) to a transaction described in Article IV, Section B(e)(1) wherein such holder is contributing, selling, transferring or otherwise disposing of shares of the Corporation’s capital stock to such counterparty (or Affiliate thereof) as part of a “rollover” or similar transaction that is in connection with such transaction.

 

  (f)

Conversion of Class B Common Stock.

 

  (1)

Optional Conversion of Class B Common Stock. At the option of the holder thereof, each share of Class B Common Stock shall be convertible, at any time or from time to time, into one fully paid and nonassessable share of Class A Common Stock. Each holder of Class B Common Stock who elects to convert any share of Class B Common Stock into a share of Class A Common Stock shall surrender the certificate or certificates therefor (if any), duly endorsed, at the office of the Corporation or any transfer agent for Class B Common Stock, or notify the Corporation or its transfer agent that such certificates have been lost, stolen or destroyed, and shall give written notice to the Corporation at such office that such holder elects to convert the same and shall state therein the number of shares of Class B Common Stock being converted. Such conversion shall be deemed to have been made immediately prior to the close of business on the date of such surrender of the certificate or certificates representing the shares of Class B Common Stock to be converted to the Corporation or its transfer agent or, in the case of lost, stolen or destroyed certificates, on the date of delivery to the Corporation or its transfer agent of such notice of such conversion (accompanied by such notice that such certificates have been lost, stolen or destroyed), and the Person entitled to receive the shares of Class A Common Stock issuable upon such conversion shall be treated for all purposes as the record holder of such shares of Class A Common Stock at such time.

 

5


  (2)

Automatic Conversion of Class B Common Stock Upon Transfer. Each share of Class B Common Stock shall automatically convert into one fully paid and nonassessable share of Class A Common Stock upon a Transfer, other than to a Permitted Transferee, of such share of Class B Common Stock. Such conversion shall occur automatically without the need for any further action by the holders of such shares and whether or not the certificates representing such shares (if any) are surrendered to the Corporation or its transfer agent.

 

  (3)

Reservation of Shares. The Corporation shall at all times reserve and keep available out of its authorized but unissued shares of Class A Common Stock, solely for the purpose of effecting the conversion of the shares of Class B Common Stock, as applicable, such number of its shares of Class A Common Stock as shall from time to time be sufficient to effect the conversion of all outstanding shares of Class B Common Stock; and if at any time the number of authorized but unissued shares of Class A Common Stock shall not be sufficient to effect the conversion of all then-outstanding shares of Class B Common Stock, as applicable, the Corporation will take such corporate action as may be necessary to increase its authorized but unissued shares of Class A Common Stock to such numbers of shares as shall be sufficient for such purpose.

C. Preferred Stock. The Board of Directors is hereby empowered, without any action or vote by the Corporation’s stockholders (except as may otherwise be provided by the terms of any series of Preferred Stock then outstanding), to authorize by resolution or resolutions from time to time the issuance of one or more series of Preferred Stock and to fix such voting powers, full or limited, or no voting powers, and such designations, powers, preferences and relative, participating, optional or other rights, if any, and the qualifications, limitations or restrictions thereof, if any, with respect to each such series of Preferred Stock and the number of shares constituting each such series, and to increase or decrease the number of shares of any such series to the extent permitted by the DGCL, as shall be set forth in a certificate of designations adopted by the Board of Directors and filed in accordance with the DGCL.

ARTICLE V

BOARD OF DIRECTORS

A. Number of Directors; Composition of the Board of Directors.

 

  (a)

The business and affairs of the Corporation shall be managed by, or under the direction of, the Board of Directors. Unless and except to the extent that the Bylaws shall so require, the election of Directors need not be by written ballot. Before the Trigger Date, the Board of Directors will consist of a single class of Directors each elected annually at the annual meeting of stockholders. Subject to the rights of the holders of any series of Preferred Stock then outstanding, the total number of Directors shall be fixed exclusively by the Board of Directors; provided, however, that before the Trigger Date, stockholders may also fix the number of Directors by resolution adopted by the stockholders by written consent in lieu of a meeting.

 

6


B. Preferred Directors. Notwithstanding anything else contained herein, whenever the holders of one or more series of Preferred Stock shall have the right, voting separately as a series, to elect Directors, the election, term of office, filling of vacancies, removal and other features of such directorships shall be governed by the terms of such series of Preferred Stock provided in the applicable certificate of designations adopted by the Board of Directors pursuant to Article IV hereof.

C. Classified Board of Directors. From and after the Trigger Date, the Board of Directors shall be divided into three (3) classes, as nearly equal in number as reasonably practicable, designated Class I, Class II and Class III. Class I Directors shall initially serve until the first annual meeting of stockholders following the Trigger Date; Class II Directors shall initially serve until the second annual meeting of stockholders following the Trigger Date; and Class III Directors shall initially serve until the third annual meeting of stockholders following the Trigger Date. Immediately following the Trigger Date, the Board of Directors is authorized to designate the Directors then in office as Class I Directors, Class II Directors or Class III Directors. Commencing with the first annual meeting of stockholders following the Trigger Date and for each annual meeting of stockholders thereafter, Directors of the class the term of which shall then expire shall be elected to hold office for a term ending on the date of the third annual meeting of stockholders next following the annual meeting at which such Directors were elected. In the event of any change in the number of Directors, the Board of Directors shall apportion any newly created directorships among, or reduce the number of directorships in, such class or classes as shall equalize, as nearly as reasonably practicable, the number of Directors in each class. In no event will a decrease in the number of Directors shorten the term of any incumbent director.

D. Vacancy and Newly Created Directorships. Subject to the rights of the holders of any series of Preferred Stock then outstanding, newly created directorships resulting from any increase in the authorized number of Directors or any vacancies on the Board of Directors resulting from death, resignation, disqualification, removal from office or other cause shall be filled only by the affirmative vote of a majority of the voting power of the remaining Directors then in office, even if less than a quorum of the Board of Directors (excluding the vote of any such Director who has resigned, even if such resignation has not yet become effective); provided, however, that before the Trigger Date, vacancies may also be filled by the stockholders by the affirmative vote of the holders of a majority of the total combined voting power of the outstanding Common Stock entitled to vote generally in the election of Directors, voting together as a single class. If there are no Directors in office, then an election of Directors may be held in accordance with the DGCL. Any director so chosen shall hold office until the next election of the class for which such director shall have been chosen and until his or her successor shall be duly elected and qualified or until such director’s earlier death, disqualification, resignation or removal. No decrease in the number of Directors shall shorten the term of any director then in office.

E. Removal of Directors. Subject to the rights of the holders of any series of Preferred Stock then outstanding, any director or the entire Board of Directors may be removed from office at any time, but only for cause, by the affirmative vote of the holders of seventy-five percent (75%) of the total combined voting power of the outstanding Common Stock entitled to vote generally in the election of Directors, voting together as a single class; provided, however, that before the Trigger Date, any director may be removed with or without cause by affirmative vote of the holders of a majority of the total combined voting power of the outstanding Common Stock entitled to vote generally in the election of Directors, voting together as a single class.

 

7


ARTICLE VI

MEETINGS OF STOCKHOLDERS

A. Annual Meetings. An annual meeting of stockholders for the election of Directors to succeed those whose terms expire and for the transaction of such other business as may properly come before the meeting shall be held at such place, on such date, if any, and at such time as the Board of Directors (or its designee) shall determine.

B. Special Meetings. Subject to the rights of the holders of any series of Preferred Stock then outstanding and to the requirements of the DGCL, special meetings of the stockholders of the Corporation may be called only (1) by or at the direction of the Board of Directors pursuant to the affirmative vote of a majority of the total number of Directors that the Corporation would have if there were no vacancies or (2) by or at the direction of the Chairman or the Chief Executive Officer; provided, however, that before the Trigger Date, special meetings of stockholders of the Corporation may also be called by the Secretary of the Corporation at the request of the holders of a majority of the total combined voting power of the outstanding Common Stock entitled to vote generally in the election of Directors, voting together as a single class. Any business transacted at any special meeting of stockholders shall be limited to matters relating to the purpose or purposes stated in the notice of meeting. From and after the Trigger Date, the ability of the stockholders of the Corporation to call a special meeting is specifically denied. Notwithstanding the foregoing, whenever holders of one or more series of Preferred Stock shall have the right, voting separately as a series, to elect directors, such holders may call, pursuant to the terms of such series of Preferred Stock adopted by resolution or resolutions of the Board of Directors pursuant to Article IV hereof, special meetings of holders of such Preferred Stock.

C. Action by Written Consent. Any action required or permitted to be taken by the stockholders of the Corporation may be effected only at a duly called annual or special meeting of stockholders of the Corporation and may not be effected by any consent by such stockholders; provided, however, that before the Trigger Date, any action required or permitted to be taken by the stockholders of the Corporation may be effected by the consent of the holders of a majority of the total combined voting power of the outstanding Common Stock entitled to vote generally in the election of Directors, acting together as a single class, in lieu of a duly called annual or special meeting of stockholders.

ARTICLE VII

INDEMNIFICATION

A. Limited Liability. To the fullest extent permitted by the DGCL, no director or officer of the Corporation shall be personally liable to the Corporation or its stockholders for monetary damages for breach of fiduciary duty as a director or officer. If the DGCL is amended to authorize corporate action further eliminating or limiting the personal liability of directors or officers, then the liability of a director or officer of the Corporation shall be eliminated or limited

 

8


to the fullest extent permitted by the DGCL, as so amended. Any amendment, repeal or elimination of this Article VII, or the adoption of any provision of this Certificate of Incorporation inconsistent with this Article VII, shall not affect its application with respect to an act or omission by a director or officer occurring before such amendment, adoption, repeal or elimination. Solely for purposes of this Article VII, “officer” shall have the meaning provided in Section 102(b)(7) of the DGCL.

 

  B.

Right to Indemnification.

 

  (a)

Each person (and the heirs, executors or administrators of such person) who was or is a party or is threatened to be made a party to, or is involved in any threatened, pending or completed action, suit or proceeding, whether civil, criminal, administrative or investigative, by reason of the fact that such person is or was a director or officer of the Corporation or is or was serving at the request of the Corporation as a director or officer of another corporation, partnership, joint venture, trust or other enterprise, shall be indemnified and held harmless by the Corporation to the fullest extent permitted by applicable law. The right to indemnification conferred in this Article VII shall also include the right to be paid by the Corporation the expenses incurred in connection with any such proceeding in advance of its final disposition to the fullest extent authorized by applicable law. Notwithstanding the foregoing, except with respect to proceedings to enforce rights to indemnification or advancement of expenses or with respect to any compulsory counterclaim brought by such indemnitee, the Corporation shall indemnify any such indemnitee in connection with a proceeding (or part thereof) initiated by such indemnitee only if such proceeding (or part thereof) was authorized by the Board of Directors.

 

  (b)

The Corporation may, by action of its Board of Directors, provide indemnification to such of the employees and agents of the Corporation to such extent and to such effect as the Board of Directors (or its designee) shall determine to be appropriate and authorized by applicable law.

C. Insurance. The Corporation shall have power to purchase and maintain insurance on behalf of any person who is or was a director, officer, employee or agent of the Corporation, or is or was serving at the request of the Corporation as a director, officer, employee or agent of another corporation, partnership, joint venture, trust or other enterprise against any expense, liability or loss incurred by such person in any such capacity or arising out of such person’s status as such, whether or not the Corporation would have the power to indemnify such person against such liability under applicable law.

D. Nonexclusivity of Rights. The rights and authority conferred in this Article VII shall not be exclusive of any other right that any person may otherwise have or hereafter acquire.

E. Preservation of Rights. Neither the amendment nor repeal of this Article VII, nor the adoption of any contrary provision of this Certificate of Incorporation or the Bylaws, nor, to the fullest extent permitted by applicable law, any modification of law, shall adversely affect any right or protection of any person granted pursuant hereto existing at, arising out of or related to any event, act or omission that occurred prior to the time of such amendment, repeal, adoption or modification (regardless of when any proceeding (or part thereof) relating to such event, act or omission arises or is first threatened, commenced or completed).

 

9


ARTICLE VIII

BYLAWS

In furtherance and not in limitation of the powers conferred by law, the Board of Directors is expressly authorized to make, alter, amend or repeal the Bylaws. The stockholders entitled to vote shall also have the power to make, alter, amend or repeal the Bylaws; provided, however, that from and after the Trigger Date, in addition to any other vote otherwise required by law, the affirmative vote of the holders of seventy-five percent (75%) of the total combined voting power of the outstanding Common Stock entitled to vote generally in the election of Directors, voting together as a single class, shall be required to make, alter, amend or repeal the Bylaws.

ARTICLE IX

AMENDMENTS

A. Adoption, Amendment and Repeal of Certificate of Incorporation. Subject to Article IV hereof, the Corporation reserves the right to amend, alter, change or repeal any provision contained in this Certificate of Incorporation, in the manner now or hereafter prescribed by the DGCL, and all rights, preferences and privileges of whatsoever nature conferred upon stockholders, directors or any other Persons whomsoever by and pursuant to this Certificate of Incorporation in its present form or as hereafter amended, are granted and held subject to this reservation. Notwithstanding anything to the contrary contained in this Certificate of Incorporation, and notwithstanding that a lesser percentage may be permitted from time to time by applicable law, no provision of Articles IV (Section B only), V, VI, VII, VIII, IX or X (or any applicable definitions from Article XII) may be altered, amended or repealed in any respect, nor may any provision or Bylaw inconsistent therewith be adopted, unless in addition to any other vote required by this Certificate of Incorporation or otherwise required by law, (i) before the Trigger Date, such alteration, amendment, repeal or adoption is approved by, in addition to any other vote otherwise required by law, the affirmative vote of the holders of a majority of the total combined voting power of the outstanding Common Stock entitled to vote thereon, voting together as a single class and (ii) from and after the Trigger Date, such alteration, amendment, repeal or adoption is approved by, in addition to any other vote otherwise required by law, the affirmative vote of the holders of seventy-five percent (75%) of the total combined voting power of the outstanding Common Stock entitled to vote thereon, voting together as a single class, at a meeting of the stockholders called for that purpose.

B. Severability. If any provision or provisions of this Certificate of Incorporation shall be held to be invalid, illegal or unenforceable as applied to any circumstance for any reason whatsoever: (i) the validity, legality and enforceability of such provisions in any other circumstance and of the remaining provisions of this Certificate of Incorporation (including, without limitation, each portion of any paragraph of this Certificate of Incorporation containing any such provision held to be invalid, illegal or unenforceable that is not itself held to be invalid, illegal or unenforceable) shall not in any way be affected or impaired thereby and (ii) to the

 

10


fullest extent possible, the provisions of this Certificate of Incorporation (including, without limitation, each such portion of any paragraph of this Certificate of Incorporation containing any such provision held to be invalid, illegal or unenforceable) shall be construed so as to permit the Corporation to protect its Directors, officers, employees and agents from personal liability in respect of their good faith service to or for the benefit of the Corporation to the fullest extent permitted by law.

ARTICLE X

DGCL SECTION 203

Until the earlier of the time (i) at which VGP and the VGP Entities, collectively, no longer beneficially own, in the aggregate, at least fifteen percent (15%) of the total combined voting power of the outstanding Common Stock entitled to vote generally in the election of Directors, and (ii) the Board of Directors has determined that the Corporation will be subject to the restrictions set forth in Section 203 of the DGCL and has given written notice to VGP that the Corporation irrevocably agrees that VGP and the VGP entities shall not be subject to the restrictions on business combinations set forth in Section 203 of the DGCL, the Corporation hereby expressly elects not to be governed by Section 203 of the DGCL, and the restrictions contained in Section 203 shall not apply to the Corporation. From and after such time, the Corporation shall be governed by Section 203 so long as Section 203 by its terms would apply to the Corporation; provided that, if the Board of Directors made a determination and provided the notice contemplated by clause (ii) of this Article X, then VGP and the VGP Entities shall not be subject to the restrictions on “interested stockholders” from and after such time.

ARTICLE XI

EXCLUSIVE FORUM

Unless the Corporation consents in writing to the selection of an alternative forum, the Court of Chancery of the State of Delaware shall be the sole and exclusive forum for the following types of actions or proceedings under Delaware statutory or common law: (i) any derivative action or proceeding brought by or on behalf of the Corporation; (ii) any action or proceeding asserting a claim of breach of a fiduciary duty owed by any current or former director, officer or other employee of the Corporation or any stockholder to the Corporation or the Corporation’s stockholders; (iii) any action or proceeding asserting a claim against the Corporation or any current or former director, officer or other employee of the Corporation or any stockholder arising pursuant to any provision of the DGCL, this Certificate of Incorporation or the Bylaws; (iv) any action or proceeding to interpret, apply, enforce or determine the validity of this Certificate of Incorporation or the Bylaws (including any right, obligation or remedy thereunder); (v) any action or proceeding as to which the DGCL confers jurisdiction to the Court of Chancery of the State of Delaware; and (vi) any action asserting a claim against the Corporation or any director, officer or other employee of the Corporation or any stockholder, governed by the internal affairs doctrine, in all cases to the fullest extent permitted by law and subject to the court’s having personal jurisdiction over the indispensable parties named as defendants. This Article XI shall not apply to suits brought to enforce a duty or liability created by the Securities Exchange Act of 1934, as amended, or any other claim for which the federal courts have exclusive jurisdiction. Unless the Corporation consents in writing to the selection of an alternative forum, the federal district courts of the United States of America shall be the

 

11


exclusive forum for the resolution of any complaint asserting a cause or causes of action arising under the Securities Act of 1933, as amended, including all causes of action asserted against any defendant named in such complaint. For the avoidance of doubt, this provision is intended to benefit and may be enforced by the Corporation, its officers and Directors, the underwriters to any offering giving rise to such complaint, and any other professional entity whose profession gives authority to a statement made by that person or entity and who has prepared or certified any part of the documents underlying the offering. Any Person holding, owning or otherwise acquiring any interest in shares of capital stock of the Corporation shall be deemed to have notice of and to have consented to the provisions of this Article XI.

ARTICLE XII

DEFINITIONS

As used in this Certificate of Incorporation, unless the context otherwise requires or as set forth in another article of this Certificate of Incorporation, the following capitalized terms shall have the following meanings as used herein:

Affiliate” means, with respect to any specified Person, any other Person who, directly or indirectly, controls, is controlled by, or is under common control with such Person, including without limitation any partner, member, officer or director of such Person.

beneficial ownership” or “beneficially own” shall have the meaning as defined under Rule 13d-3 and Rule 13d-6 of the Exchange Act.

Board of Directors” means the board of directors of the Corporation.

Bylaws” means the Amended and Restated Bylaws of the Corporation, as amended from time to time.

Certificate of Incorporation” means this Second Amended and Restated Certificate of Incorporation of the Corporation, as amended and restated from time to time.

Chairman” means the chairperson or, if applicable, any co-chairperson of the Board of Directors.

Class A Common Stock” has the meaning set forth in Article IV, Section A.

Class B Common Stock” has the meaning set forth in Article IV, Section A.

close of business” means 5:00 p.m., New York City time.

Common Stock” has the meaning set forth in Article IV, Section A.

control” means the possession, directly or indirectly, of the power to direct or cause the direction of management or policies (whether through ownership of securities or any partnership or other ownership interest, by contract or otherwise) of a Person.

Corporation” has the meaning set forth in Article I.

 

12


Directors” means the directors of the Corporation.

Effective Time” means the time that this Certificate of Incorporation filed with the Secretary of State of the State of Delaware became effective in accordance with the DGCL.

Estate Planning Entity” means with respect to any VGP Owner or any member of the Immediate Family of such VGP Owner, (i) any trust, the beneficiaries of which are primarily such VGP Owner or any member of his or her Immediate Family or (ii) any entity that is primarily owned or controlled, directly or indirectly, by a VGP Owner or member of his or her Immediate Family and/or any of the Persons described in clause (i).

Immediate Family” means, with respect to any individual, collectively, his or her parents, brothers, sisters, spouse, former spouses, civil union partner, former civil union partner, and lineal descendants (and the estates, guardians, custodians or other legal representatives of any of the foregoing).

Liquidation Event” means any liquidation, dissolution, or winding up of the Corporation, whether voluntary or involuntary.

Permitted Transferee” means, VGP, Robert Pender, Michael Sabel, or any VGP Related Person.

Person” means a natural person, partnership (whether general or limited), limited liability company, trust (including a common law trust, business trust, statutory trust, voting trust or any other form of trust), estate, association (including any group, organization, co-tenancy, plan, board, council or committee), corporation, government (including a country, state, county or any other governmental subdivision, agency or instrumentality), custodian, nominee or any other individual or entity (or series thereof) in its own or any representative capacity, in each case, whether domestic or foreign.

Preferred Stock” has the meaning set forth in Article IV, Section A.

Transfer” of a share of Class B Common Stock means any sale, assignment, transfer or disposition of such share, whether or not for value and whether voluntary or involuntary or by operation of law; provided, however, that none of the following shall be considered a “Transfer”:

(i) the granting of a revocable proxy to (A) officers or Directors or agents of the Corporation at the request of the Board of Directors in connection with actions to be taken at an annual or special meeting of stockholders or by written consent or (B) any other person with specific direction to vote such shares of Class B Common Stock as directed by the holder of such shares, without discretion, in connection with actions to be taken at an annual or special meeting of stockholders;

(ii) entering into a voting trust, agreement or arrangement (with or without granting a proxy and, if a proxy is granted, whether revocable or irrevocable) solely with holders of Class B Common Stock (in that capacity) that (A) is disclosed either in a Schedule 13D filed with the Securities and Exchange Commission or in writing to the Secretary of the Corporation, (B) either has a term not exceeding one (1) year or is terminable by the holder of the shares subject thereto at any time and (C) does not involve any payment of cash, securities, property or other consideration to the holder of the shares subject thereto other than the mutual promise to vote shares in a designated manner;

 

13


(iii) the pledge of shares of Class B Common Stock that creates a mere security interest in such shares pursuant to a bona fide loan or indebtedness transaction (it being understood that a foreclosure pursuant to such pledge shall constitute a Transfer);

(iv) entering into, or reaching an agreement, arrangement or understanding regarding, a support or similar voting or tender agreement (with or without granting a proxy and, if a proxy is granted, whether revocable or irrevocable) or any “rollover,” in each case, in connection with any transaction or series of related transactions, or any liquidation, dissolution and winding up of the Corporation that has been approved by the Board of Directors; or

(v) the spouse of any holder of Class B Common Stock possessing or obtaining an interest in such holder’s shares of Class B Common Stock arising solely by reason of the application of the community property laws of any jurisdiction.

A “Transfer” shall also be deemed to have occurred with respect to a share of Class B Common Stock beneficially owned by a Permitted Transferee on the date that such Permitted Transferee ceases to meet the qualifications to be a Permitted Transferee.

Trigger Date” means the first time at which either (i) VGP and the VGP Entities, collectively, no longer beneficially own, in the aggregate, more than fifty percent (50%) of the total combined voting power of the outstanding Common Stock entitled to vote generally in the election of Directors, or (ii) the Corporation fails to qualify as a “controlled company” (or similar) under the applicable stock exchange rules and regulations.

VGP” means Venture Global Partners II, LLC.

VGP Entities” means any Person that constitutes a Permitted Transferee of VGP.

VGP Owner” means any individual that is a direct or indirect beneficial owner of VGP.

VGP Related Person” means any Affiliate of VGP, any member of the Immediate Family of any VGP Owner or any Estate Planning Entities.

 

14


IN WITNESS WHEREOF, this Second Amended and Restated Certificate of Incorporation of Venture Global, Inc. has been duly executed by the officer below this [•] day of [•], 2024.

 

Venture Global, Inc.
By:    
  Name: [•]
  Title: [•]

 

15

Exhibit 3.2

FORM OF AMENDED AND RESTATED

BYLAWS

OF

VENTURE GLOBAL, INC.

(adopted as of [•], 2024)

* * * * *

ARTICLE 1

OFFICES

Section 1.01. Registered Office. The registered agent of Venture Global, Inc. (the “Corporation”) is The Corporation Trust Company. The registered office of the Corporation in the State of Delaware is to be located at 1209 Orange Street, City of Wilmington, County of New Castle, Delaware 19801.

Section 1.02. Other Offices. The Corporation may also have offices at such other places both within and without the State of Delaware as the board of directors of the Corporation (the “Board of Directors”) may from time to time determine or the business of the Corporation may require.

Section 1.03. Books. The books of the Corporation may be kept within or without the State of Delaware as the Board of Directors may from time to time determine or the business of the Corporation may require.

ARTICLE 2

MEETINGS OF STOCKHOLDERS

Section 2.01. Time and Place of Meetings. All meetings of stockholders shall be held at such place, if any, either within or without the State of Delaware, on such date and at such time as may be determined from time to time by the Board of Directors (or the chairperson or, if applicable, any co-chairperson of the Board of Directors (collectively, the “Chairperson”) in the absence of a designation by the Board of Directors). The Board of Directors may, in its sole discretion, determine that a meeting of stockholders shall not be held at any place, but may instead be held solely by means of remote communication as authorized under the DGCL (defined below). If no determination is made by the Board of Directors, the place of meeting shall be the principal office of the Corporation.

Section 2.02. Annual Meetings. An annual meeting of stockholders shall be held for the election of directors and to transact such other business as may properly be brought before the meeting.

Section 2.03. Special Meetings. Special meetings of the stockholders of the Corporation may be called in the manner set forth in the Second Amended and Restated Certificate of Incorporation of the Corporation filed with the Secretary of State of the State of Delaware on [•], 2024 (as the same may be amended, restated, amended and restated or otherwise modified from time to time, the “Certificate of Incorporation”).


Section 2.04. Notice of Meetings and Adjourned Meetings; Waivers of Notice.

(a) Whenever stockholders are required or permitted to take any action at a meeting, a notice of the meeting shall be given which shall state the place, if any, date and hour of the meeting, the means of remote communications, if any, by which stockholders and proxy holders may be deemed to be present in person and vote at such meeting, and, in the case of a special meeting, the purpose or purposes for which the meeting is called. Unless otherwise provided by the General Corporation Law of the State of Delaware as the same exists or may hereafter be amended (the “DGCL”), the Certificate of Incorporation or these Amended and Restated Bylaws (the “Bylaws”), such notice shall be given not less than 10 nor more than 60 days before the date of the meeting to each stockholder of record entitled to vote at such meeting. The Board of Directors or the chairperson of the meeting may adjourn the meeting to another time or place (whether or not a quorum is present), and notice need not be given of the adjourned meeting if the time, place, if any, and the means of remote communications, if any, by which stockholders and proxy holders may be deemed to be present in person and vote at such meeting, are announced at the meeting at which such adjournment is made or provided in any other manner permitted by the DGCL. At the adjourned meeting, the Corporation may transact any business which might have been transacted at the original meeting. If the adjournment is for more than 30 days, or after the adjournment a new record date is fixed for the adjourned meeting, a notice of the adjourned meeting shall be given to each stockholder of record entitled to vote at the meeting.

(b) A written waiver of any such notice signed by the person entitled thereto, or a waiver by electronic transmission by the person entitled to notice, whether before or after the time stated therein, shall be deemed equivalent to notice. Attendance of a person at a meeting shall constitute a waiver of notice of such meeting, except when the person attends the meeting for the express purpose of objecting, at the beginning of the meeting, to the transaction of any business because the meeting is not lawfully called or convened. Business transacted at any special meeting of stockholders shall be limited to the purposes stated in the notice.

Section 2.05. Quorum. Unless otherwise required by the Certificate of Incorporation, these Bylaws or the DGCL, the presence, in person or by proxy, of the holders of a majority of the total combined voting power of all outstanding securities of the Corporation generally entitled to vote generally at a meeting of stockholders shall constitute a quorum for the transaction of business. If, however, such quorum shall not be present or represented at any meeting of the stockholders, the chairperson of the meeting or the stockholders, by the affirmative vote of a majority of the voting power present in person or represented by proxy, may adjourn the meeting, without notice other than announcement at the meeting, until a quorum shall be present or represented. At such adjourned meeting at which a quorum shall be present or represented, any business may be transacted that might have been transacted at the meeting as originally noticed.

Section 2.06. Voting.

(a) The voting rights for the holders of Class A common stock (“Class A Common Stock”) of the Corporation and Class B common stock (“Class B Common Stock” and together with Class A Common Stock, “Common Stock”) of the Corporation shall be determined in the manner set forth in the Certificate of Incorporation. Except as otherwise required by law, the Certificate of Incorporation or these Bylaws, in all matters other than the election of directors, the affirmative vote of the holders of a majority of the votes cast at the meeting on the subject matter shall be the act of the stockholders. Abstentions and broker non-votes shall not be counted as votes cast. Subject to the rights of the holders of any

 

2


series of preferred stock to elect additional directors under specific circumstances, as may be set forth in the certificate of designations for such series of preferred stock, directors shall be elected by a plurality of the votes cast in respect of the shares present in person or represented by proxy at the meeting and entitled to vote generally in the election of directors.

(b) Each stockholder entitled to vote at a meeting of stockholders or to express consent or dissent to a corporate action in writing without a meeting may authorize another person or persons to act for such stockholder by proxy in the manner permitted by law. No proxy shall be voted after three (3) years from its date, unless said proxy provides for a longer period.

Section 2.07. Action by Consent. Any action required or permitted to be taken at any annual or special meeting of stockholders may be taken only upon the vote of stockholders at an annual or special meeting duly noticed and called in accordance with the DGCL and may not be taken by consent of stockholders without a meeting, except as set forth in the Certificate of Incorporation, and subject to the rights of the holders of any series of preferred stock then outstanding, as may be set forth in the certificate of designations for such series of preferred stock.

Section 2.08. Organization. At each meeting of stockholders, the Chairperson, if one shall have been elected, or in the Chairperson’s absence or if one shall not have been elected, the director designated by the affirmative vote of the majority of the directors present at such meeting, shall act as chairperson of the meeting. The Secretary (or in the Secretary’s absence or inability to act, the person whom the chairperson of the meeting shall appoint secretary of the meeting) shall act as secretary of the meeting and keep the minutes thereof.

Section 2.09. Order of Business. The order of business at all meetings of stockholders shall be as determined by the chairperson of the meeting.

Section 2.10. Inspector of Elections. The Corporation may, and to the extent required by law, shall, in advance of any meeting of stockholders, appoint one or more inspectors to act at the meeting and make a written report thereof. The Corporation may designate one or more alternate inspectors to replace any inspector who fails to act. If no inspector or alternate is able to act at a meeting of stockholders, the chairperson of the meeting may, and to the extent required by law, shall, appoint one or more inspectors to act at the meeting. Each inspector, before entering upon the discharge of his or her duties, shall take and sign an oath faithfully to execute the duties of inspector with strict impartiality and according to the best of his or her ability. Every vote taken by ballots shall be counted by a duly appointed inspector or inspectors.

Section 2.11. Nomination of Directors and Proposal of Other Business.

(a) Annual Meetings of Stockholders. (i) Nominations of persons for election to the Board of Directors or the proposal of other business to be transacted by the stockholders at an annual meeting of stockholders may be made only (A) pursuant to the Corporation’s notice of meeting (or any supplement thereto), (B) by or at the direction of the Board of Directors or any committee thereof duly authorized, (C) as may be provided in the certificate of designations for any series of preferred stock or (D) by any stockholder of the Corporation who is a stockholder of record at the time of giving of notice provided for in paragraph (ii) of this Section 2.11(a) and at the time of the annual meeting, who shall be entitled to vote at the meeting and who complies with the procedures set forth in this Section 2.11(a), and, except as otherwise required by law, any failure to comply with these procedures shall result in the

 

3


nullification of such nomination or proposal. For the avoidance of doubt, the foregoing clause (D) shall be the exclusive means for a stockholder to make nominations or propose other business at an annual meeting of stockholders (other than a proposal included in the Corporation’s proxy statement pursuant to and in compliance with Rule 14a-8 under the Securities and Exchange Act of 1934, as amended, and together with the rules and regulations promulgated thereunder, the “Exchange Act”).

(ii) For nominations or other business to be properly brought before an annual meeting of stockholders by a stockholder pursuant to clause (D) of paragraph (i) of this Section 2.11(a), (A) the stockholder must have given timely notice thereof in writing to the Secretary of the Corporation and must have complied with the requirements and provisions hereof and (B) any such proposed business (other than the nominations of persons for election to the Board of Directors) must constitute a proper matter for stockholder action under Delaware law. To be timely, a stockholder’s notice shall be delivered to, or mailed and received by, the Secretary of the Corporation at the principal executive offices of the Corporation not later than the close of business on the 120th day nor earlier than the close of business on the 150th day prior to the first anniversary of the preceding year’s annual meeting of stockholders (which prior year’s annual meeting shall, for purposes of the Corporation’s first annual meeting of stockholders following its initial public offering of shares of its Class A Common Stock, be deemed to have occurred on May 15, 2024); provided, however, that in the event that the date of the annual meeting is advanced more than 30 days prior to such anniversary date or delayed more than 70 days after such anniversary date, or if no annual meeting was held (or deemed held) in the preceding year, then to be timely such notice must be received by the Corporation not later than the close of business on the later of the 120th day prior to the date of the meeting or the 10th day following the day on which public announcement of the date of the meeting was first made by the Corporation nor earlier than the close of business on the 150th day prior to such annual meeting. The minimum timeliness requirements of this paragraph shall apply despite any different timeline described in Rule 14a-19 or elsewhere in Regulation 14A under the Exchange Act, including with respect to any statements or information required to be provided to the Corporation pursuant to Rule 14a-19 of the Exchange Act by a stockholder and not otherwise specified herein. In no event shall the adjournment, recess or postponement of any meeting, or any announcement thereof, commence a new time period (or extend any time period) for the giving of a stockholder’s notice as described above. The number of nominees a stockholder may nominate for election at the annual meeting on its own behalf (or in the case of a stockholder giving the notice on behalf of a beneficial owner, the number of nominees a stockholder may nominate for election at the annual meeting on behalf of such beneficial owner) shall not exceed the number of directors to be elected at such annual meeting.

Notwithstanding anything in this Section 2.11 to the contrary, in the event that the number of directors to be elected to the Board of Directors at an annual meeting of stockholders is increased effective after the time period for which nominations would otherwise be due under this Section 2.11 and there is no public announcement by the Corporation naming the nominees for the additional directorships or specifying the size of the increased Board of Directors at least 100 days prior to the first anniversary of the preceding year’s annual meeting of stockholders (or deemed meeting), a stockholder’s notice required by this Section 2.11 shall also be considered timely, but only with respect to nominees for any new directorships created by such increase, if it shall be delivered to, and received by, the Secretary at the principal executive offices of the Corporation not later than the 10th day following the day on which such public announcement is first made by the Corporation.

 

4


(iii) A stockholder’s notice to the Secretary shall set forth:

(A) as to each person whom the stockholder proposes to nominate for election or reelection as a director:

(1) the name, age, business address and residence address of such person;

(2) the principal occupation or employment of such person;

(3) (i) for each class or series, the number of shares of capital stock of the Corporation that are held of record or are beneficially owned (and proof of any such beneficial ownership) by such person and any affiliates or associates (each within the meaning of Rule 12b-2 promulgated under the Exchange Act for purposes of these Bylaws) of such person, including any such shares that such person, or any affiliates or associates of such person, has the right to acquire beneficial ownership of, (ii) the name of each nominee holder of shares of all capital stock of the Corporation owned beneficially (and proof of any such beneficial ownership) but not of record by such person or any affiliates or associates of such person, and the number of such shares of each class or series of capital stock held by each such nominee holder, including any such shares that such nominee holder has the right to acquire beneficial ownership of, (iii) any agreement, arrangement, relationship or understanding pursuant to which such person, or any affiliates or associates of such person, has a right to vote any shares of any security of the Corporation, (iv) a description of any agreement, arrangement or understanding (including, regardless of the form of settlement, any derivative, long or short positions, profit interests, forwards, futures, swaps, options, warrants, convertible securities, stock appreciation or similar rights, hedging transactions and borrowed or loaned shares) that has been entered into by or on behalf of, or any other agreement, arrangement or understanding that has been made, the effect or intent of which is to create or mitigate loss to, manage risk or benefit of share price changes for, or increase or decrease the voting power of, such person, or any affiliates or associates of such person, with respect to the Corporation’s securities, and (v) any direct or indirect interest of such person, or any affiliates or associates of such person, in any employment agreement, collective bargaining agreement or consulting agreement with the Corporation;

(4) all information relating to such person, or any affiliates or associates of such person, that is required to be disclosed in solicitations of proxies for election of directors, or is otherwise required, in each case pursuant to Regulation 14A under the Exchange Act;

 

5


(5) all completed and signed questionnaires in the same form as those questionnaires required of the Corporation’s directors (which will be provided to such person within 5 business days following a written request therefor);

(6) a statement that such person has read the Corporation’s corporate governance guidelines and any other Corporation policies and guidelines applicable to directors (which will be provided to such person within 5 business days following a written request therefor), and a written agreement from such person to adhere to the foregoing policies and guidelines, as amended from time to time, if he or she is elected as a director;

(7) an executed agreement by such person: (i) consenting to serve as a director if elected and (if applicable) to being named in a proxy statement and/or form of proxy relating to the meeting at which directors are to be elected, along with a representation that such person intends to serve a full term as a director if elected, and (ii) that such person is not and will not become a party to (x) any direct or indirect compensatory, payment or other financial agreement, arrangement or understanding with any other person or entity other than the Corporation, in each case in connection with candidacy or service as a director of the Corporation (a “Third-Party Compensation Arrangement”) that has not been fully disclosed to the Corporation prior to, or concurrently with, the submission of the notice from the stockholder required by this Section 2.11, (y) any agreement, arrangement or understanding, including the amount of any payment or payments received or receivable thereunder, with any other person or entity as to how such person would vote or act on any issue or question as a director (a “Voting Commitment”) that has not been fully disclosed to the Corporation prior to, or concurrently with, the submission of the notice from the stockholder required by this Section 2.11 or (z) any Voting Commitment that could limit or interfere with such person’s ability to comply, if elected as a director of the Corporation, with such person’s fiduciary duties under applicable law; and

(8) such other information reasonably requested by the Corporation to determine whether such person is qualified under the Certificate of Incorporation, these Bylaws, the rules or regulations of any stock exchange applicable to the Corporation, or any law or regulation applicable to the Corporation to serve as a director and/or independent director of the Corporation;

(B) as to any other business that the stockholder proposes to bring before the meeting:

(1) a brief description of the business desired to be brought before the meeting;

(2) the text of the proposal or business (including the text of any resolutions proposed for consideration and in the event that such business includes a proposal to amend these Bylaws, the text of the proposed amendment);

 

6


(3) the reasons for conducting such business; and

(4) any substantial interest (within the meaning of Item 5 of Schedule 14A under the Exchange Act) in such business of such stockholder and the beneficial owner, if any, on whose behalf the proposal is made;

(C) as to the stockholder giving the notice and the beneficial owner, if any, on whose behalf the nomination or proposal is made:

(1) the name and address of such stockholder (as they appear on the Corporation’s books) and any such beneficial owner;

(2) a representation as to whether such stockholder or such beneficial owner has complied with all applicable legal requirements in connection with its acquisition of shares or other securities of the Corporation;

(3) a written agreement from such stockholder that it is a holder of record of stock of the Corporation entitled to vote at such meeting and intends to appear at the meeting in person or through a qualified representative to make such nomination or proposal;

(4) in the case of a nomination, a written agreement from such stockholder (and such beneficial owner) that it (or they) will not submit any substitute nominations unless they are made within the time periods set forth in this Section 2.11 and the stockholder and the substitute nominees will otherwise comply with this Section 2.11;

(5) in the case of a nomination, a written agreement from such stockholder (and such beneficial owner) that it (or they) has not, and shall not, nominate a number of nominees (inclusive of substitutes) that exceeds the number of directors to be elected at the annual meeting; and

(6) a written agreement that such stockholder (and such beneficial owner) shall (i) update and supplement the notice required by this Section 2.11, if necessary, so that the information provided or required in such notice shall be true and correct as of the record date for determining the stockholders entitled to receive notice of the annual meeting, and as of the date that is 5 business days prior to the meeting or any adjournment or postponement thereof and (ii) deliver such update and supplement so that it is received by the Secretary at the principal executive offices of the Corporation (A) not later than the later of (x) 5 business days after the record date for determining the stockholders entitled to receive notice of the annual meeting and (y) 5 business days after the first

 

7


public announcement of such record date, in the case of any update and supplement required to be made as of the record date, and (B) not later than 5 business days before the meeting or any adjournment or postponement thereof, in the case of any update and supplement required to be made as of the date that is 5 business days prior to the meeting or any adjournment or postponement thereof. For the avoidance of doubt, the obligation to update and supplement as set forth in this Section 2.11 or any other section of these Bylaws shall not limit the Corporation’s rights with respect to any deficiencies in any stockholder’s notice, extend any applicable deadlines under these Bylaws or enable or be deemed to permit a stockholder who has previously submitted a stockholder’s notice under these Bylaws to amend or update any proposal or to submit any new proposal, including by changing or adding nominees, matters, business and/or resolutions proposed to be brought before a meeting of stockholders;

(D) as to each of the stockholder giving the notice, the beneficial owner, if any, on whose behalf the nomination or proposal is made, and, if such stockholder or beneficial owner is an entity, each person controlling, controlled by or under common control with such stockholder or beneficial owner (each such person or entity contemplated by this clause (D), a “Proposing Person”):

(1) for each class or series, the number of shares of capital stock of the Corporation that are held of record or are beneficially owned (and proof of any such beneficial ownership) by such Proposing Person, or any associates (within the meaning of Rule 12b-2 promulgated under the Exchange Act for purposes of these Bylaws) of such Proposing Person, including any such shares that such Proposing Person, or any associates of such Proposing Person, has the right to acquire beneficial ownership of;

(2) the name of each nominee holder of each class or series of capital stock of the Corporation that are owned beneficially (and proof of any such beneficial ownership) but not of record by such Proposing Person, or any associates of such Proposing Person, and the number of such shares of each class or series of capital stock of the Corporation held by each such nominee holder, including any such shares that such nominee holder has the right to acquire beneficial ownership of;

(3) a description of any agreement, arrangement, relationship or understanding pursuant to which such Proposing Person, or any associates of such Proposing Person, has a right to vote any shares of any security of the Corporation;

(4) a description of any material pending or threatened legal proceeding in which such Proposing Person is a party or material participant involving the Corporation or any of its officers or directors, or any affiliate of the Corporation;

 

8


(5) a description of (i) any plans or proposals which any such Proposing Person may have with respect to securities of the Corporation that would be required to be disclosed pursuant to Item 4 of Exchange Act Schedule 13D (regardless of whether the requirement to file a Schedule 13D is applicable) and (ii) any agreement, arrangement or understanding (including the identity of the parties thereto) with respect to the nomination or other business between or among such Proposing Parties and any other parties, including without limitation any agreements that would be required to be disclosed pursuant to Item 5 or Item 6 of Exchange Act Schedule 13D (regardless of whether the requirement to file a Schedule 13D is applicable), in each case as of the date the notice required by this Section 2.11 is delivered to the Corporation by the stockholder, or beneficial owner in such business, if any, presenting the nomination or other proposal;

(6) a description of any agreement, arrangement or understanding (including, regardless of the form of settlement, any derivative, long or short positions, profit interests, forwards, futures, swaps, options, warrants, convertible securities, stock appreciation or similar rights, hedging transactions and borrowed or loaned shares) that has been entered into by or on behalf of, or any other agreement, arrangement or understanding that has been made, the effect or intent of which is to create or mitigate loss to, manage risk or benefit of share price changes for, or increase or decrease the voting power of, such Proposing Person, or any associates of such Proposing Person, with respect to the Corporation’s securities;

(7) a written representation as to whether any Proposing Person, or any other participant as defined in Item 4 of Schedule 14A under the Exchange Act, will engage in a solicitation with respect to such nomination or other business and, if so, whether such solicitation will be conducted as an exempt solicitation under Rule 14a-2(b) of the Exchange Act, the name of each participant in such solicitation and the amount of the cost of solicitation that has been and will be borne, directly or indirectly, by each participant in such solicitation and (x) in the case of a proposal of business other than nominations, whether such person or group intends to deliver a proxy statement and/or form of proxy to holders of at least the percentage of the Corporation’s voting shares required under applicable law to carry the proposal, (y) in the case of any solicitation that is subject to Rule 14a-19 of the Exchange Act, confirming that such person or group will deliver, through means satisfying each of the conditions that would be applicable to the Corporation under either Exchange Act Rule 14a-16(a) or Exchange Act Rule 14a-16(n), a proxy statement and/or form of proxy to holders of at least sixty-seven percent (67%) of the voting power of the Corporation’s capital stock entitled to vote generally in the election of directors and/or (z) whether such person or group intends to otherwise solicit proxies or votes from holders in support of such proposal or nomination (for purposes of this clause (7), the term “holders” shall include, in addition to stockholders of record, any beneficial owners pursuant to Rule 14b-1 and Rule 14b-2 of the Exchange Act);

 

9


(8) a representation that promptly after any Proposing Person solicits the holders of the Corporation’s stock referred to in the representation required under the preceding clause, and in any event no later than 5 business days before the applicable meeting, such Proposing Person will provide the Corporation with reasonable documentary evidence (as determined by the Corporation or one of its representatives, acting in good faith), which may take the form of a certified statement and documentation from a proxy solicitor, specifically demonstrating that the necessary steps have been taken to deliver a proxy statement and/or form of proxy to holders of such percentage of the Corporation’s stock;

(9) any direct or indirect interest of such Proposing Person, or any associates of such Proposing Person, in any contract (including, in any such case, any employment agreement, collective bargaining agreement or consulting agreement) with the Corporation, or any affiliate of the Corporation;

(10) any other information relating to such Proposing Person, or any associates of such Proposing Person, or proposed business that would be required to be disclosed in a proxy statement or other filing required to be made in connection with the solicitation of proxies in support of such nominee or proposal pursuant to Section 14 of the Exchange Act; and

(11) such other information relating to any proposed item of business as the Corporation may reasonably require to determine whether such proposed item of business is a proper matter for stockholder action.

(b) Special Meetings of Stockholders. If the election of directors is included as business to be brought before a special meeting in the Corporation’s notice of meeting, then nominations of persons for election to the Board of Directors at a special meeting of stockholders may be made only by or at the direction of the Board of Directors or by any stockholder who is a stockholder of record at the time of giving of notice provided for in this Section 2.11(b) and at the time of the special meeting, who shall be entitled to vote at the meeting and who complies with the procedures set forth in this Section 2.11(b); provided, however, that the number of nominees a stockholder may nominate for election at the special meeting on its own behalf (or in the case of a stockholder giving the notice on behalf of a beneficial owner, the number of nominees a stockholder may nominate for election at the special meeting on behalf of such beneficial owner) shall not exceed the number of directors to be elected at such special meeting. For nominations to be properly brought by a stockholder before a special meeting of stockholders pursuant to this Section 2.11(b), the stockholder must have given timely notice thereof in writing to the Secretary of the Corporation. To be timely, a stockholder’s notice shall be delivered to, or mailed and received at, the principal executive offices of the Corporation not later than the close of business on the later of the 120th day prior to the date of the special meeting and the 10th day following the day on which public announcement of the date of the special meeting was first made nor earlier than the close of business on the 150th day prior to the date of the special meeting. A stockholder’s notice to the Secretary shall comply with the notice

 

10


requirements of Section 2.11(a)(iii). The minimum timeliness requirements of this paragraph shall apply despite any different timeline described in Rule 14a-19 or elsewhere in Regulation 14A under the Exchange Act, including with respect to any statements or information required to be provided to the Corporation pursuant to Rule 14a-19 of the Exchange Act by a stockholder and not otherwise specified herein. In no event shall the adjournment, recess or postponement of a special meeting, or any announcement thereof, commence a new time period (or extend any time period) for the giving of a stockholder’s notice as described above. Such notice of a stockholder shall include the same information, representations, certifications and agreements that would be required if the stockholder were to make a nomination in connection with an annual meeting of stockholders pursuant to the preceding provisions of this Section 2.11, and such stockholder shall be obligated to provide the same supplemental or additional information in connection with a special meeting of stockholders as required pursuant to the preceding provisions of this Section 2.11 in connection with an annual meeting of stockholders.

(c) General. (i) No person shall be eligible to be nominated by a stockholder to be elected or reelected at any meeting of stockholders to serve as a director of the Corporation unless nominated in accordance with the procedures set forth in this Section 2.11. No business proposed by a stockholder shall be conducted at a stockholder meeting except in accordance with this Section 2.11.

(ii) Without limiting any remedy available to the Corporation, and unless otherwise determined by the Board of Directors, the Chairperson of the Board of Directors or the chairperson of the meeting, a stockholder may not present nominations for director or business proposals at an annual or special meeting of stockholders (and any such nominee shall be disqualified from standing for election), notwithstanding proxies or votes may have been solicited and/or received with respect thereto, if such stockholder, any beneficial owner, any Proposing Person or any nominee or substitute nominee for director: (A) acted contrary to any representation, statement, certification or agreement required by the applicable provisions of these Bylaws; (B) otherwise failed to comply with these Bylaws or with any law, rule or regulation identified in these Bylaws, including all applicable requirements of the Exchange Act and the rules and regulations thereunder with respect to the matters set forth in this Section 2.11; provided, however, that any references in these Bylaws to the Exchange Act or the rules and regulations promulgated thereunder are not intended to and shall not limit any requirements applicable to nominations or proposals as to any other business to be considered pursuant to this Section 2.11; or (C) provided information to the Corporation (whether required by these Bylaws or otherwise) that is false, misleading, inaccurate or incomplete in any material respect. The Board of Directors, the Chairperson of the Board of Directors or the chairperson of the meeting shall, if the facts warrant, determine and declare to the meeting that a nomination was not made in accordance with the procedures prescribed by these Bylaws or that business was not properly brought before the meeting, and if he/she should so determine, he/she shall so declare to the meeting and the defective nomination shall be disregarded or such business shall not be transacted, as the case may be. Notwithstanding the foregoing provisions of this Section 2.11, unless otherwise required by law, if the stockholder (or a qualified representative of the stockholder) does not appear at the annual or special meeting of stockholders of the Corporation to present a nomination or other proposed business, such nomination shall be disregarded or such proposed business shall not be transacted, as the case may be, notwithstanding that proxies in respect of such vote may have been received by the Corporation and counted for purposes of determining a quorum. For purposes of this Section 2.11, to be

 

11


considered a qualified representative of the stockholder, a person must be a duly authorized officer, manager or partner of such stockholder or must be authorized by a writing executed by such stockholder or an electronic transmission delivered by such stockholder to act for such stockholder as proxy at the meeting of stockholders and such person must produce such writing or electronic transmission, or a reliable reproduction of the writing or electronic transmission, at the meeting of stockholders.

Upon request by the Corporation, if any Proposing Person (i) provides notice pursuant to Rule 14a-19(b) promulgated under the Exchange Act (or has previously filed a preliminary or definitive proxy statement with the information required by Rule 14a-19(b)) with respect to any proposed nominee for election as a director of the Corporation and (ii) subsequently fails to comply with the requirements of Rule 14a-19(a)(2) or Rule 14a-19(a)(3) promulgated under the Exchange Act (or fails to timely provide reasonable evidence sufficient to satisfy the Corporation that such Proposing Person has met the requirements of Rule 14a-19(a)(3) promulgated under the Exchange Act in accordance with the following sentence), then the nomination of each such proposed nominee shall be disregarded, notwithstanding that the nominee is included as a nominee in the Corporation’s proxy statement, notice of meeting or other proxy materials for any meeting (or any supplement thereto) and notwithstanding that proxies or votes in respect of the election of such proposed nominees may have been received by the Corporation (which proxies and votes shall be disregarded). Upon request by the Corporation, if any Proposing Person provides notice pursuant to Rule 14a-19(b) promulgated under the Exchange Act (or has previously filed a preliminary or definitive proxy statement with the information required by Rule 14a-19(b)), such Proposing Person, shall deliver to the Corporation, no later than five (5) business days prior to the applicable meeting, reasonable evidence that it has met the requirements of Rule 14a-19(a)(3) promulgated under the Exchange Act.

(iii) Compliance with paragraphs (a) and (b) of this Section 2.11 shall be the exclusive means for a stockholder to make nominations or submit other business (other than as provided in Section 2.11(c)(iv)).

(iv) For the avoidance of doubt, nothing in this Section 2.11 shall be deemed to affect any rights of (A) stockholders to request inclusion of proposals in the Corporation’s proxy statement pursuant to Rule 14a-8 under the Exchange Act or (B) the holders of any series of preferred stock of the Corporation to make nominations of persons for election to the Board of Directors if and to the extent provided for under law, the Certificate of Incorporation or these Bylaws Notwithstanding anything to the contrary, the notice requirements set forth herein with respect to the proposal of any business pursuant to this Section 2.11 shall be deemed satisfied by a stockholder if such stockholder has submitted a proposal to the Corporation in compliance with Rule 14a-8 under the Exchange Act, and such stockholder’s proposal has been included in a proxy statement that has been prepared by the Corporation to solicit proxies for the meeting of stockholders.

(v) Any stockholder directly or indirectly soliciting proxies from other stockholders in connection with any annual or special meeting of stockholders must use a proxy card color other than white, which shall be reserved for the exclusive use for solicitation by or on behalf of the Board of Directors.

 

12


(vi) Whenever this Section 2.11 requires one or more persons (including a record or beneficial owner of stock) to deliver a document or information to the Corporation or any officer, employee or agent thereof (including any notice, request, questionnaire, revocation, representation, statement or other document or agreement), the Corporation shall not be required to accept delivery of such document or information unless the document or information is in writing exclusively (and not in an electronic transmission) and delivered exclusively by hand (including, without limitation, overnight courier service) or by certified or registered mail, return receipt requested.

(vii) For purposes of these Bylaws, (A) “public announcement” means disclosure in a press release reported by PR Newswire or a comparable national news service or in a document publicly filed by the Corporation with the Securities and Exchange Commission pursuant to Section 13, 14, or 15(d) of the Exchange Act, (B) “business day” means any day other than Saturday, Sunday or a day on which banks are closed in New York City, New York; and (C) “close of business” means 5:00 p.m. local time at the principal executive offices of the Corporation on any calendar day, whether or not the day is a business day.

(viii) Advance Notice Exceptions. Notwithstanding anything to the contrary herein, so long as Venture Global Partners II, LLC (“VGP”) and any VGP Entities (as defined in the Certificate of Incorporation), collectively, hold at least 5% of the total combined voting power of the outstanding Common Stock entitled to vote generally in the election of directors, VGP and any VGP Entities shall not be subject to the notice procedures set forth in Section 2.11 with respect to any annual or special meeting of stockholders.

ARTICLE 3

DIRECTORS

Section 3.01. General Powers. Except as otherwise provided in the DGCL or the Certificate of Incorporation, the business and affairs of the Corporation shall be managed by or under the direction of the Board of Directors.

Section 3.02. Number, Election and Term of Office. The number of directors that shall constitute the Board of Directors, and any classes thereof, shall be not less than three (3) nor more than eleven (11) and shall be fixed in the manner provided in the Certificate of Incorporation. The term of each director shall be set as specified in the Certificate of Incorporation. Directors need not be stockholders of the Corporation to be qualified for election or service as a director.

Section 3.03. Quorum and Manner of Acting. Unless the Certificate of Incorporation or these Bylaws require a greater number, a majority of the entire Board of Directors shall constitute a quorum for the transaction of business at any meeting of the Board of Directors and, except as otherwise expressly required by law or by the Certificate of Incorporation, the affirmative vote of a majority of the directors present at a meeting at which a quorum is present shall be the act of the Board of Directors. When a meeting is adjourned to another time or place (whether or not a quorum is present), notice need not be given of the adjourned meeting if the time and place thereof are announced at the meeting at which the adjournment is taken. At the adjourned meeting, the Board of Directors may transact any business which might have been transacted at the original meeting. If a quorum shall not be present at any meeting of the Board of Directors, the directors present thereat shall adjourn the meeting, from time to time, without notice other than announcement at the meeting, until a quorum shall be present.

 

13


Section 3.04. Time and Place of Meetings. The Board of Directors shall hold its meetings at such place, if any, either within or without the State of Delaware, and at such time as may be determined from time to time by (or in the manner determined by) the Board of Directors (or the Chairperson in the absence of a determination by the Board of Directors).

Section 3.05. Annual Meeting. The Board of Directors may meet for the purpose of organization, the election of officers and the transaction of other business, as soon as practicable after each annual meeting of stockholders. Notice of such meeting need not be given. In the event such annual meeting is not so held, the annual meeting of the Board of Directors may be held at such place, if any, either within or without the State of Delaware, on such date and at such time as shall be specified in a notice thereof given as hereinafter provided in Section 3.07 herein or in a waiver of notice thereof signed by any director who chooses to waive the requirement of notice.

Section 3.06. Regular Meetings. After the place, if any, and time of regular meetings of the Board of Directors shall have been determined and notice thereof shall have been once given to each member of the Board of Directors, regular meetings may be held without further notice being given.

Section 3.07. Special Meetings. Special meetings of the Board of Directors may be called by the Chairperson or the President and shall be called by the Chairperson, President or the Secretary, on the written request of three directors.

(a) Notice of the time and place of special meetings shall be:

(i) delivered personally by hand, by courier, or by telephone;

(ii) sent by United States first-class mail, postage prepaid;

(iii) sent by facsimile or electronic mail; or

(iv) sent by other means of electronic transmission, directed to each director at that director’s address, telephone number, facsimile number, or electronic mail address, or other address for electronic transmission, as the case may be, as shown on the Corporation’s records.

(b) If the notice is (i) delivered personally by hand, by courier, or by telephone, (ii) sent by facsimile or electronic mail, or (iii) sent by other means of electronic transmission, it shall be delivered or sent, as applicable, at least forty-eight (48) hours before the time of the holding of the meeting. If the notice is sent by U.S. mail, it shall be deposited in the U.S. mail at least four (4) days before the time of the holding of the meeting. The notice need not specify the place of the meeting, if any (if the meeting is to be held at the Corporation’s principal executive office) nor the purpose of the meeting.

Section 3.08. Committees. Subject to the provisions of the Certificate of Incorporation, the Board of Directors may designate one or more committees, each committee to consist of one or more of the directors of the Corporation, and may designate one or more directors as alternate members of any committee, who may replace any absent or disqualified member at any meeting of the committee. In the absence or disqualification of a member of a committee, the member or members present at any meeting and not disqualified from voting, whether or not such member or members constitute a quorum, may unanimously appoint another member of the Board of Directors to act at the meeting in the place of any such absent or disqualified member. Any such committee, to the extent

 

14


provided in the resolution of the Board of Directors, shall have and may exercise all the powers and authority of the Board of Directors in the management of the business and affairs of the Corporation, and may authorize the seal of the Corporation to be affixed to all papers which may require it; but no such committee shall have the power or authority in reference to the following matters: (a) approving or adopting, or recommending to the stockholders, any action or matter (other than the election or removal of directors) expressly required by the DGCL to be submitted to the stockholders for approval or (b) adopting, amending or repealing any Bylaw of the Corporation. Each committee shall keep regular minutes of its meetings and report the same to the Board of Directors when required.

Section 3.09. Action by Consent. Unless otherwise restricted by the Certificate of Incorporation or these Bylaws, any action required or permitted to be taken at any meeting of the Board of Directors or of any committee thereof may be taken without a meeting, if all members of the Board of Directors or committee, as the case may be, consent thereto in writing or by electronic transmission, and any consent may be documented, signed and delivered in any manner permitted by the DGCL. After an action is taken, the consent or consents relating thereto shall be filed with the minutes of proceedings of the Board of Directors or committee in the same paper or electronic form as the minutes are maintained.

Section 3.10. Telephonic Meetings. Unless otherwise restricted by the Certificate of Incorporation or these Bylaws, members of the Board of Directors, or any committee designated by the Board of Directors, may participate in a meeting of the Board of Directors, or such committee, as the case may be, by means of conference telephone or other communications equipment by means of which all persons participating in the meeting can hear each other, and such participation in a meeting shall constitute presence in person at the meeting.

Section 3.11. Resignation. Any director may resign from the Board of Directors at any time by giving notice in writing or by electronic transmission to the Board of Directors or to the Secretary of the Corporation. The resignation of any director shall take effect upon receipt of notice thereof or at such later time as shall be specified in such notice; and unless otherwise specified therein, the acceptance of such resignation shall not be necessary to make it effective.

Section 3.12. Vacancies. Vacancies on the Board of Directors resulting from death, resignation, removal or otherwise and newly created directorships resulting from any increase in the authorized number of directors shall be filled in the manner set forth in the Certificate of Incorporation. Any director so chosen shall hold office until the next election of the class for which such director shall have been chosen and until his or her successor shall be duly elected and qualified or until such director’s earlier death, disqualification, resignation or removal. No decrease in the number of directors shall shorten the term of any director then in office.

Section 3.13. Removal. Directors may be removed from office at any time only in the manner set forth in the Certificate of Incorporation.

Section 3.14. Compensation. Unless otherwise restricted by the Certificate of Incorporation or these Bylaws, the Board of Directors shall have authority to fix the compensation of directors, including fees and reimbursement of expenses.

 

15


Section 3.15. Preferred Stock Directors. Notwithstanding anything else contained herein, whenever the holders of one or more series of preferred stock shall have the right, voting separately as a series, to elect directors, the election, term of office, filling of vacancies, removal and other features of such directorships shall be governed by the terms of the resolutions applicable thereto adopted by the Board of Directors pursuant to the Certificate of Incorporation, and such directors so elected shall not be subject to the provisions of Sections 3.02, 3.12 and 3.13 of this Article 3 unless otherwise provided therein.

ARTICLE 4

OFFICERS

Section 4.01. Principal Officers. The principal officers of the Corporation shall be appointed by, or in the manner determined by, the Board of Directors and may consist of a Chief Executive Officer, a President, an Executive Chairperson or Executive Co-Chairperson, one or more Vice Presidents, a Treasurer and a Secretary. The Corporation may also have such other principal officers, including one or more Controllers, as the Board of Directors may in its discretion appoint. One person may hold the offices and perform the duties of any two or more of said offices, and one office may be held by more than one person and each such person may perform the duties of such office, except that no one person shall hold the offices and perform the duties of President and Secretary.

Section 4.02. Appointment, Term of Office and Remuneration. The principal officers of the Corporation shall be appointed by, or in the manner determined by, the Board of Directors or, other than in the case of an appointment of a Chief Executive Officer or an Executive Chairperson or an Executive Co-Chairperson, by the Chief Executive Officer. Each such officer shall hold office for such period as the Board of Directors may from time to time determine and until their successor is appointed, or until their earlier death, resignation, retirement, disqualification or removal. The remuneration of all officers of the Corporation shall be fixed by, or in the manner determined by, the Board of Directors. Any vacancy in any office shall be filled in such manner as the Board of Directors shall determine.

Section 4.03. Subordinate Officers. In addition to the principal officers enumerated in Section 4.01 herein, the Corporation may have one or more Assistant Treasurers, Assistant Secretaries and Assistant Controllers and such other subordinate officers, agents and employees as the Board of Directors may deem necessary, each of whom shall hold office for such period as the Board of Directors (or its designee) may from time to time determine. The Board of Directors may delegate to any principal officer the power to appoint and to remove any such subordinate officers, agents or employees.

Section 4.04. Removal. Except as otherwise permitted with respect to subordinate officers, any officer may be removed, with or without cause, at any time, by or in the manner determined by the Board of Directors or, other than in the case of any removal of a Chief Executive Officer or an Executive Chairperson or an Executive Co-Chairperson, by the Chief Executive Officer.

Section 4.05. Resignations. Any officer may resign at any time by giving notice to the Board of Directors (or to a principal officer if the Board of Directors has delegated to such principal officer the power to appoint and to remove such officer). Any such notice must be in writing or by electronic transmission. The resignation of any officer shall take effect upon receipt of notice thereof or at such later time as shall be specified in such notice; and unless otherwise specified therein, the acceptance of such resignation shall not be necessary to make it effective.

Section 4.06. Powers and Duties. The officers of the Corporation shall have such powers and perform such duties incident to each of their respective offices and such other duties as may from time to time be conferred upon or assigned to them by, or in the manner determined by, the Board of Directors.

 

16


ARTICLE 5

CAPITAL STOCK

Section 5.01. Certificates for Stock; Uncertificated Shares. The shares of the Corporation shall be represented by certificates, provided that the Board of Directors may provide by resolution or resolutions that some or all of any or all classes or series of its stock shall be uncertificated shares or a combination of certificated and uncertificated shares. Any such resolution that shares of a class or series will only be uncertificated shall not apply to shares represented by a certificate until such certificate is surrendered to the Corporation. Except as otherwise required by law, the rights and obligations of the holders of uncertificated shares and the rights and obligations of the holders of shares represented by certificates of the same class and series shall be identical. Every holder of stock represented by certificates shall be entitled to have a certificate representing the number of shares registered in certificate form signed by or in the name of the Corporation by any two officers of the Corporation authorized to sign stock certificates, including the Chief Executive Officer, the President, any Vice President, the Treasurer, any Assistant Treasurer, the Secretary, any Assistant Secretary, and any other authorized officer. Any or all of the signatures on the certificate may be a facsimile. In case any officer, transfer agent or registrar who has signed or whose facsimile signature has been placed upon a certificate shall have ceased to be such officer, transfer agent or registrar before such certificate is issued, it may be issued by the Corporation with the same effect as if such person were such officer, transfer agent or registrar at the date of issue. The Corporation shall not have power to issue a certificate in bearer form.

Section 5.02. Lost Certificates. The Corporation may issue a new certificate of stock or uncertificated shares in the place of any certificate theretofore issued by it that is alleged to have been lost, stolen or destroyed, and the Corporation may require the owner of the lost, stolen or destroyed certificate, or such owner’s legal representative, to give the Corporation a bond sufficient to indemnify it against any claim that may be made against it on account of the alleged loss, theft or destruction of any such certificate or the issuance of such new certificate or uncertificated shares.

Section 5.03. Shares Without Certificates. The Corporation may adopt a system of issuance, recordation and transfer of its shares of stock by electronic or other means not involving the issuance of certificates, provided the use of such system by the Corporation is permitted in accordance with the DGCL.

Section 5.04. Transfer of Shares. Shares of the stock of the Corporation may be transferred on the record of stockholders of the Corporation by the holder thereof or by such holder’s duly authorized attorney upon surrender of a certificate therefor properly endorsed or upon receipt of proper transfer instructions from the registered holder of uncertificated shares or by such holder’s duly authorized attorney and upon compliance with appropriate procedures for transferring shares in uncertificated form, unless waived by the Corporation.

Section 5.05. Authority for Additional Rules Regarding Transfer. The Board of Directors shall have the power and authority to make all such rules and regulations as they may deem expedient concerning the issue, transfer and registration of certificated or uncertificated shares of the stock of the Corporation, as well as for the issuance of new certificates in lieu of those which may be lost or destroyed, and may require of any stockholder requesting replacement of lost or destroyed certificates, bond in such amount and in such form as they may deem expedient to indemnify the Corporation, and/or the transfer agents, and/or the registrars of its stock against any claims arising in connection therewith.

 

17


ARTICLE 6

INDEMNIFICATION

Section 6.01. Limited Liability. As provided in the Certificate of Incorporation, a director and an officer of the Corporation shall not be liable to the Corporation or its stockholders for monetary damages for breach of fiduciary duty as a director or officer to the fullest extent permitted by applicable law.

Section 6.02. Right to Indemnification. (a) Each person (and the heirs, executors or administrators of such person) who was or is a party or is threatened to be made a party to, or is involved in any threatened, pending or completed action, suit or proceeding, whether civil, criminal, administrative or investigative, by reason of the fact that such person is or was a director or officer of the Corporation or while an officer or director of the Corporation is or was serving at the request of the Corporation as a director or officer of another corporation, partnership, joint venture, trust or other enterprise, shall be indemnified and held harmless by the Corporation to the fullest extent permitted by applicable law. The right to indemnification conferred in this Article 6 shall also include the right to be paid by the Corporation the expenses incurred in connection with any such proceeding in advance of its final disposition to the fullest extent authorized by applicable law. The right to indemnification conferred in this Article 6 shall be a contract right, provided, however, that, except with respect to proceedings to enforce rights to indemnification or advancement of expenses or with respect to any compulsory counterclaim brought by such indemnitee, the Corporation shall indemnify any such indemnitee in connection with a proceeding (or part thereof) initiated by such indemnitee only if such proceeding (or part thereof) was authorized by the Board of Directors.

(b) The Corporation may, by action of its Board of Directors, provide indemnification to such of the employees and agents of the Corporation to such extent and to such effect as the Board of Directors shall determine to be appropriate and authorized by applicable law.

Section 6.03. Insurance. The Corporation shall have power to purchase and maintain insurance on behalf of any person who is or was a director, officer, employee or agent of the Corporation, or is or was serving at the request of the Corporation as a director, officer, employee or agent of another corporation, partnership, joint venture, trust or other enterprise against any expense, liability or loss incurred by such person in any such capacity or arising out of such person’s status as such, whether or not the Corporation would have the power to indemnify such person against such liability under applicable law.

Section 6.04. Nonexclusivity of Rights. The rights and authority conferred in this Article 6 shall not be exclusive of any other right that any person may otherwise have or hereafter acquire.

Section 6.05. Preservation of Rights. Neither the amendment nor repeal of this Article 6, nor the adoption of any contrary provision of the Certificate of Incorporation or these Bylaws, nor, to the fullest extent permitted by applicable law, any modification of law, shall adversely affect any right or protection of any person granted pursuant hereto existing at, arising out of or related to any event, act or omission that occurred prior to the time of such amendment, repeal, adoption or modification (regardless of when any proceeding (or part thereof) relating to such event, act or omission arises or is first threatened, commenced or completed).

 

18


ARTICLE 7

EMERGENCY BYLAWS

Section 7.01. Emergency By-Laws. This Article 7 shall be operative during any emergency condition as contemplated by Section 110 of the DGCL (an “Emergency”), notwithstanding any different or conflicting provisions in the Articles of these Bylaws, the Certificate of Incorporation, or the DGCL.

Section 7.02. Quorum. In the event of an Emergency, as a result of which a quorum of the Board of Directors or of a committee of the Board of Directors cannot readily be convened for action at a meeting of the Board of Directors or a committee, then the director or directors in attendance at such meeting shall constitute a quorum. Such director or directors in attendance may further take action to appoint one or more of themselves or other directors to membership on any standing or temporary committees of the Board of Directors as they shall deem necessary and appropriate.

Section 7.03. Other Powers. Except as the Board of Directors may otherwise determine, during any Emergency, the Corporation, and its directors and officers, may exercise any authority and take any action or measure contemplated by Section 110 of the DGCL.

ARTICLE 8

GENERAL PROVISIONS

Section 8.01. Fixing the Record Date. (a) In order that the Corporation may determine the stockholders entitled to notice of any meeting of stockholders or any adjournment thereof, the Board of Directors may fix a record date, which record date shall not precede the date upon which the resolution fixing such record date is adopted by the Board of Directors, and which record date shall not be more than 60 nor less than 10 days before the date of such meeting. If the Board of Directors so fixes a date, such date shall also be the record date for determining the stockholders entitled to vote at such meeting unless the Board of Directors determines, at the time it fixes such record date, that a later date on or before the date of the meeting shall be the date for making such determination. If no record date is fixed by the Board of Directors, the record date for determining stockholders entitled to notice of or to vote at a meeting of stockholders shall be at the close of business on the day next preceding the day on which notice is given, or, if notice is waived, at the close of business on the day next preceding the day on which the meeting is held. A determination of stockholders of record entitled to notice of or to vote at a meeting of stockholders shall apply to any adjournment of the meeting; provided, however, that the Board of Directors may in its discretion or as required by law fix a new record date for determination of stockholders entitled to vote at the adjourned meeting, and in such case shall fix the same date or an earlier date as the record date for stockholders entitled to notice of such adjourned meeting.

(b) In order that the Corporation may determine the stockholders entitled to consent to corporate action without a meeting, the Board of Directors may fix a record date, which record date shall not precede the date upon which the resolution fixing the record date is adopted by the Board of Directors, and which date shall not be more than 10 days after the date upon which the resolution fixing the record date is adopted by the Board of Directors. If no record date has been fixed by the Board of Directors, the record date for determining

 

19


stockholders entitled to consent to corporate action without a meeting, when no prior action by the Board of Directors is required by the DGCL, shall be the first date on which a signed consent setting forth the action taken or proposed to be taken is delivered to the Corporation by delivery to its registered office in Delaware, its principal place of business, or an officer or agent of the Corporation having custody of the book in which proceedings of meetings of stockholders are recorded. If no record date has been fixed by the Board of Directors and prior action by the Board of Directors is required by the DGCL, the record date for determining stockholders entitled to consent to corporate action without a meeting shall be at the close of business on the day on which the Board of Directors adopts the resolution taking such prior action.

(c) In order that the Corporation may determine the stockholders entitled to receive payment of any dividend or other distribution or allotment of any rights or the stockholders entitled to exercise any rights in respect of any change, conversion or exchange of stock, or for the purpose of any other lawful action, the Board of Directors may fix a record date, which record date shall not precede the date upon which the resolution fixing the record date is adopted, and which record date shall be not more than 60 days prior to such action. If no record date is fixed, the record date for determining stockholders for any such purpose shall be at the close of business on the day on which the Board of Directors adopts the resolution relating thereto.

Section 8.02. Dividends. Subject to limitations contained in the DGCL and the Certificate of Incorporation, the Board of Directors may declare and pay dividends upon the shares of capital stock of the Corporation, which dividends may be paid either in cash, in property or in shares of the capital stock of the Corporation.

Section 8.03. Year. The fiscal year of the Corporation shall commence on January 1 and end on December 31 of each year.

Section 8.04. Corporate Seal. The corporate seal shall have inscribed thereon the name of the Corporation, the year of its organization and the words “Corporate Seal, Delaware”. The seal may be used by causing it or a facsimile thereof to be impressed, affixed or otherwise reproduced.

Section 8.05. Voting of Stock Owned by the Corporation. The Board of Directors may authorize any person, on behalf of the Corporation, to attend, vote at and grant proxies to be used at any meeting of stockholders or equity holders of any corporation or other entity (except this Corporation) in which the Corporation may hold stock or other equity.

Section 8.06. Construction. These Bylaws are adopted subject to any applicable law and the Certificate of Incorporation. Whenever these Bylaws may conflict with any applicable law or the Certificate of Incorporation, such conflict shall be resolved in favor of such law or the Certificate of Incorporation.

Section 8.07. Amendments. The Board of Directors, by the affirmative vote of a majority, shall have the power to adopt, amend or repeal these Bylaws. These Bylaws may be altered, amended or repealed, or new Bylaws may be made, by the stockholders of the Corporation in the manner set forth in the Certificate of Incorporation or as otherwise required by applicable law.

 

20

Exhibit 4.1

LOGO

INCORPORATED UNDER THE CUSIP XXXXXX XX X LAWS OF THE STATE SEE REVERSE FOR CERTAIN OF DELAWARE DEFINITIONS AND LEGENDS This certifies that BY: COUNTERSIGNED is the record holder of AND EQUINITI FULLY PAID AND NONASSESSABLE SHARES OF CLASS A COMMON STOCK, $0.01 PAR VALUE PER SHARE, OF VENTURE GLOBAL, INC. TRUST transferable on the books of the Corporation in person or by duly authorized attorney upon surrender of this Certificate properly REGISTERED: endorsed. This Certificate is not valid until countersigned by the Transfer Agent and registered by the Registrar. COMPANY, WITNESS the facsimile seal of the Corporation and the facsimile signatures of its duly authorized officers.LLC Dated: AUTHORIZED AND EGLOBTRANSFER R A U POR L, T R AT I N O E N E C C V . SIGNATURE REGISTRARAGENT SEAL DEL R E AWA


LOGO

The Corporation shall furnish without charge to each stockholder who so requests a statement of the powers, designations, preferences and relative, participating, optional or other special rights of each class of stock of the Corporation or series thereof and the qualifications, limitations or restrictions of such preferences and/or rights. Such requests shall be made to the Corporation’s Secretary at the principal office of the Corporation. KEEP THIS CERTIFICATE IN A SAFE PLACE. IF IT IS LOST, STOLEN, OR DESTROYED THE CORPORATION WILL REQUIRE A BOND INDEMNITY AS A CONDITION TO THE ISSUANCE OF A REPLACEMENT CERTIFICATE. The following abbreviations, when used in the inscription on the face of this certificate, shall be construed as though they were written out in full according to applicable laws or regulations: TEN COM – as tenants in common UNIF GIFT MIN ACT Custodian TEN ENT – as tenants by the entireties (Cust) (Minor) JT TEN – as joint tenants with right of under Uniform Gifts to Minors survivorship and not as tenants Act. (State) in common COM PROP – as community property UNIF TRF MIN ACT . Custodian (until age (Cust) (Minor) under Uniform Transfers to Minors Act (State) Additional abbreviations may also be used though not in the above list. FOR VALUE RECEIVED, hereby sell(s), assign(s) and transfer(s) unto PLEASE INSERT SOCIAL SECURITY OR OTHER IDENTIFYING NUMBER OF ASSIGNEE (PLEASE PRINT OR TYPEWRITE NAME AND ADDRESS, INCLUDING ZIP CODE, OF ASSIGNEE) shares of the capital stock represented by within Certificate, and do hereby irrevocably constitute and appoint attorney-in-fact to transfer the said stock on the books of the within named Corporation with full power of the substitution in the premises. Dated X X Signature(s) Guaranteed: NOTICE: THE SIGNATURE TO THIS ASSIGNMENT MUST CORRESPOND WITH THE NAME AS WRITTEN UPON THE FACE OF THE CERTIFICATE IN EVERY PARTICULAR, WITHOUT ALTERATION OR ENLARGEMENT OR ANY CHANGE WHATSOEVER. By THE SIGNATURE(S) SHOULD BE GUARANTEED BY AN ELIGIBLE GUARANTOR INSTITUTION, (BANKS, STOCKBROKERS, SAVINGS AND LOAN ASSOCIATIONS AND CREDIT UNIONS WITH MEMBERSHIP IN AN APPROVED SIGNATURE GUARANTEE MEDALLION PROGRAM), PURSUANT TO S.E.C. RULE 17Ad-15. GUARANTEES BY A NOTARY PUBLIC ARE NOT ACCEPTABLE. SIGNATURE GUARANTEES MUST NOT BE DATED.

Exhibit 5.1

 

LOGO   

Davis Polk & Wardwell LLP

450 Lexington Avenue
New York, NY 10017

davispolk.com

  

FORM OF OPINION OF DAVIS POLK & WARDWELL LLP

Venture Global, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Ladies and Gentlemen:

Venture Global, Inc., a Delaware corporation (the “Company”), has filed with the Securities and Exchange Commission a Registration Statement on Form S-1 (the “Registration Statement”) and the related prospectus (the “Prospectus”) for the purpose of registering under the Securities Act of 1933, as amended (the “Securities Act”), [•] shares of its Class A common stock, par value $0.01 per share (the “Securities”), including [•] shares subject to the underwriters’ option to purchase additional shares, as described in the Registration Statement.

We, as your counsel, have examined originals or copies of such documents, corporate records, certificates of public officials and other instruments as we have deemed necessary or advisable for the purpose of rendering this opinion.

In rendering the opinion expressed herein, we have, without independent inquiry or investigation, assumed that (i) all documents submitted to us as originals are authentic and complete, (ii) all documents submitted to us as copies conform to authentic, complete originals, (iii) all signatures on all documents that we reviewed are genuine, (iv) all natural persons executing documents had and have the legal capacity to do so, (v) all statements in certificates of public officials and officers of the Company that we reviewed were and are accurate and (vi) all representations made by the Company as to matters of fact in the documents that we reviewed were and are accurate.

Based upon the foregoing, and subject to the additional assumptions and qualifications set forth below, we advise you that, in our opinion, when the price at which the Securities to be sold has been approved by or on behalf of the Board of Directors of the Company and when the Securities have been issued and delivered against payment therefor in accordance with the terms of the Underwriting Agreement referred to in the prospectus which is a part of the Registration Statement, the Securities will be validly issued, fully paid and non-assessable.

In connection with the opinion expressed above, we have assumed (i) the filing of the Second Amended and Restated Certificate of Incorporation (in the form filed as Exhibit 3.1 to the Registration Statement) with the Secretary for the State of Delaware and the effectiveness thereof under Delaware Law and (ii) the adoption of the Third Amended and Restated By-Laws of the Company (in the form filed as Exhibit 3.2 to the Registration Statement), each at or prior to the time of delivery of the Shares.


LOGO

We are members of the Bar of the State of New York and the foregoing opinion is limited to the laws of the State of New York and the General Corporation Law of the State of Delaware.

We hereby consent to the filing of this opinion as an exhibit to the Registration Statement and further consent to the reference to our name under the caption “Legal Matters” in the Prospectus. In giving this consent, we do not admit that we are in the category of persons whose consent is required under Section 7 of the Securities Act.

Very truly yours,

 

2

EXHIBIT 10.1

FORM OF

AMENDED AND RESTATED SHAREHOLDERS’ AGREEMENT

of

VENTURE GLOBAL, INC.

dated as of

[  ], 2024


TABLE OF CONTENTS

 

         PAGE  
ARTICLE I

 

DEFINITIONS AND INTERPRETATION      1  

Section 1.01.

 

Definitions

     1  

Section 1.02.

 

Interpretation

     6  
ARTICLE II

 

REGISTRATION RIGHTS      6  

Section 2.01.

 

Registration Rights

     6  

Section 2.02.

 

Legends

     16  

Section 2.03.

 

Public Offering Lock-Up

     17  
ARTICLE III

 

TERM; TERMINATION      19  

Section 3.01.

 

Termination

     19  
ARTICLE IV

 

GENERAL PROVISIONS      19  

Section 4.01.

 

Notices

     19  

Section 4.02.

 

Entire Agreement

     19  

Section 4.03.

 

Successors and Assigns

     19  

Section 4.04.

 

Governing Law

     20  

Section 4.05.

 

Jurisdiction and Venue

     20  

Section 4.06.

 

Waiver of Jury Trial

     20  

Section 4.07.

 

Severability

     20  

Section 4.08.

 

No Third Party Beneficiaries

     20  

Section 4.09.

 

Joinder of Additional Holders

     20  

Section 4.10.

 

Counterparts

     20  

Section 4.11.

 

Confidentiality

     21  

Section 4.12.

 

Amendment and Waiver

     21  

 

i


AMENDED AND RESTATED SHAREHOLDERS’ AGREEMENT

THIS AMENDED AND RESTATED SHAREHOLDERS’ AGREEMENT (this “Agreement”) is made as of [  ], 2024, by and among Venture Global, Inc. (f/k/a Venture Global Holdings, Inc.), a Delaware corporation (the “Corporation”), and the Holders (as defined below) party hereto. The Corporation and each of the Holders may be referred to herein as a “Party” or collectively, as the “Parties.

RECITALS:

WHEREAS, the Holders and the Corporation are party to that certain Shareholders’ Agreement, dated as of September 25, 2023 (the “Original Agreement”);

WHEREAS, the Corporation intends to consummate the IPO (as defined below);

WHEREAS, pursuant to Section 6.2 of the Original Agreement, the Original Agreement will terminate upon the completion of the IPO, with the exception of the Post-IPO Rights (as defined in the Original Agreement);

WHEREAS, subject to certain exceptions, the Original Agreement may be amended with the written consent of (a) the Corporation and (b) the Shareholders (as defined in the Original Agreement) holding a majority of the Shares held by all Holders;

WHEREAS, as of the date hereof, Venture Global Partners II, LLC, a Delaware limited liability company (“VGP”), holds more than a majority of the Shares held by all Holders; and

WHEREAS, in connection with the IPO, VGP and the Corporation desire to amend and restate the Original Agreement, in order to terminate all provisions of the Original Agreement other than the Post-IPO Rights and to become effective upon the consummation of the IPO.

NOW, THEREFORE, for good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties, desiring to be legally bound hereby, agree that the Original Agreement is, with effect from the consummation of the IPO, amended and restated in its entirety to read as follows:

ARTICLE I

DEFINITIONS AND INTERPRETATION

Section 1.01. Definitions. Capitalized terms used in this Agreement shall have the meanings set forth below:

Accession Agreement” means an accession agreement substantially in the form set forth in Exhibit B hereto.


Affiliate” means, with respect to any specified Person, any other Person who, directly or indirectly, controls, is controlled by, or is under common control with such Person, including without limitation any partner, member, officer or director of such Person. For the purposes of this definition, “control” means the possession, directly or indirectly, of the power to direct or cause the direction of management or policies (whether through ownership of securities or any partnership or other ownership interest, by contract or otherwise) of a Person.

Agreement” has the meaning assigned to it in the preamble.

Applicable Law” means any statute, law, rule, or regulation, or any judgment, order, writ, injunction, or decree of any Governmental Authority to which a specified Person or property is subject.

Block Trade” means the sale of securities of the Corporation to one or more purchasers in a registered transaction without a prior marketing process by means of (i) a bought deal, (ii) a block trade or (iii) a direct sale.

Board of Directors” means the Board of Directors of the Corporation.

Business Day” means a day other than a Saturday, Sunday or any day on which commercial banks in New York, New York are authorized to be closed.

Charter” means the Certificate of Incorporation of the Corporation, filed with the Secretary of State of the State of Delaware, as the same may be amended or amended and restated from time to time.

Class A Common Share” means one share of the voting common stock of the Corporation designated in the Charter as “Class A Common Stock.”

Class B Common Share” means one share of the voting common stock of the Corporation designated in the Charter as “Class B Common Stock.”

Confidential Information” has the meaning assigned to that term in Section 4.12.

Corporation” has the meaning assigned to that term in the preamble.

Demand Notice” has the meaning assigned to that term in Section 2.01(b)(i).

Demand Registration” means a registration of Registrable Securities by the Corporation pursuant to Section 2.01(b), which, for the avoidance of doubt, shall include an Underwritten Takedown or an Underwritten Block Trade.

Demand Request” has the meaning assigned to that term in Section 2.01(b)(i).

Equity Securities” means the Class A Common Shares and the Class B Common Shares, any other equity securities of the Corporation, and any other securities of the Corporation convertible or exchangeable for Class A Common Shares or Class B Common Shares or other equity securities of the Corporation.

 

2


Estate Planning Entity” means with respect to any individual that is a direct or indirect beneficial owner of VGP (a “VGP Owner”) or any member of the Immediate Family of such VGP Owner, (i) any trust, the beneficiaries of which are primarily such VGP Owner or any member of his or her Immediate Family or (ii) any entity that is primarily owned or controlled, directly or indirectly, by a VGP Owner or member of his or her Immediate Family and/or any of the Persons described in clause (i).

Exchange Act” means the Securities Exchange Act of 1934, as amended, or any successor federal statute, and the rules and regulations thereunder, which shall be in effect from time to time.

Excluded Registration” means (i) a registration relating to the sale or grant of securities to employees of the Corporation or a subsidiary pursuant to a stock option, stock purchase, equity incentive or similar plan, (ii) a registration relating to a Rule 145 transaction, (iii) a registration on Form S-4 or Form S-8 or any successor or similar forms or (iv) a registration in which no Equity Securities of the Corporation are being registered other than debt securities convertible into shares of common stock and the common stock issuable upon conversion thereof.

Form S-1” means such form under the Securities Act as in effect on the date hereof or any successor registration form under the Securities Act subsequently adopted by the SEC.

Form S-3” means such form under the Securities Act as in effect on the date hereof or any registration form under the Securities Act subsequently adopted by the SEC that permits forward incorporation of substantial information by reference to other documents filed by the Corporation with the SEC.

GAAP” means United States generally accepted accounting principles and practices, consistently applied, which are recognized as such by the Financial Accounting Standards Board (or any generally recognized successor).

Governmental Authority” means any court or tribunal in any jurisdiction (domestic or foreign) or any governmental or regulatory body, agency, department, commission, board, bureau or other authority or instrumentality (domestic or foreign).

Holder” means any holder of Registrable Securities that is a party to this Agreement, including any such holder that becomes a party to this Agreement pursuant to Section 4.03 or Section 4.09, but such term does not include any Person who has ceased to be a holder of Registrable Securities.

Immediate Family” means, with respect to any person, collectively, his or her parents, brothers, sisters, spouse, former spouses, civil union partner, former civil union partner, and lineal descendants (and the estates, guardians, custodians or other legal representatives of any of the foregoing).

Initiating Holders” means, collectively, Holders who properly initiate a registration request under Section 2.01(b).

 

3


Institutional Holder” means each of the Holders holding Class A Common Shares other than VGP or any VGP Related Person.

IPO” means the first underwritten initial public offering of Class A Common Shares to be consummated by the Corporation on or about [  ], 2024.

Lead Institutional Holder” means the Holder(s) holding a majority of the Class A Common Shares held by all Institutional Holders at the applicable determination time.

Management Holders” means VGP or a transferee of Class A Common Shares or Class B Common Shares from, directly or indirectly, VGP, that is a VGP Related Person.

Person” means a natural person, partnership (whether general or limited), limited liability company, trust (including a common law trust, business trust, statutory trust, voting trust or any other form of trust), estate, association (including any group, organization, co-tenancy, plan, board, council or committee), corporation, government (including a country, state, county or any other governmental subdivision, agency or instrumentality), custodian, nominee or any other individual or entity (or series thereof) in its own or any representative capacity, in each case, whether domestic or foreign.

Piggyback Registration” has the meaning assigned to that term in Section 2.01(a)(iii).

Post-IPO Rights” has the meaning assigned to it in the preamble.

Public Offering” has the meaning assigned to that term in Section 2.03.

Registrable Securities” means (i) any Class A Common Shares owned by a Holder immediately prior to consummation of the IPO (excluding, for the avoidance of doubt, any such Class A Common Shares acquired in the IPO or thereafter), (ii) any Class A Common Shares issuable or issued by the Corporation (directly or indirectly) upon conversion of, in exchange for, or in replacement of, any Class B Common Shares owned by a Holder immediately prior to the consummation of the IPO, (iii) any Class A Common Shares issued as a dividend or other distribution with respect to the shares referenced in clauses (i) and (ii), and (iv) any security into which any Class A Common Shares referenced in clauses (i), (ii) and (iii) shall have been converted or exchanged in connection with an internal recapitalization, reorganization, reclassification or similar transaction; provided that such securities shall cease to be Registrable Securities when (a) a registration statement with respect to the sale of such securities shall have become effective under the Securities Act and such securities shall have been disposed of in accordance with such registration statement, (b) such securities shall have been sold to the public pursuant to Rule 144, or (c) (i) such securities may be sold in the public market of the United States under Rule 144 without regard to the volume or manner of sale limitations of such rule and (ii) assuming conversion of all shares of Class B Common Shares into Class A Common Shares, the Holder of such securities (together with its Affiliates that are Holders) owns less than 10.0% of the outstanding Class A Common Shares.

 

4


Registrable Securities then outstanding” means, at any time, the number of shares of Registrable Securities determined by adding, without duplication, (i) the number of outstanding Class A Common Shares that are Registrable Securities, and (ii) assuming conversion of all shares of Class B Common Shares into Class A Common Shares, the number of Class A Common Shares issuable by the Corporation (directly or indirectly) upon conversion of, in exchange for, or in replacement of, any outstanding Class B Common Shares and that are Registrable Securities, solely to the extent such Class A Common Shares are then issuable to the holder thereof.

Representatives” has the meaning assigned to that term in Section 4.12.

Restricted Securities” has the meaning assigned to that term in Section 2.02(b).

“Rule 144” means Rule 144 (or any successor or similar provision) of the Securities Act.

“Rule 145” means Rule 145 (or any successor or similar provision) of the Securities Act.

SEC” means the Securities and Exchange Commission.

Securities Act” means the Securities Act of 1933, as amended, and any successor statute thereto and the rules and regulations of the SEC promulgated thereunder.

Shareholder” means any shareholder of the Corporation that is a party to this Agreement, including those that become a party to this Agreement pursuant to Section 4.03 or Section 4.09, but such term does not include any Person who ceases to own any Class A Common Shares or Class B Common Shares.

Shareholders” has the meaning assigned to it in the preamble.

Shares” means Class A Common Shares and Class B Common Shares.

Underwritten Block Trade” has the meaning assigned to that term in Section 2.01(b)(iii).

Underwritten Block Trade Notice” has the meaning assigned to that term in Section 2.01(b)(iii).

Underwritten Takedown” has the meaning assigned to that term in Section 2.01(b)(ii).

VGP” has the meaning assigned to that term in the Recitals.

VGP Related Person” means any Affiliate of VGP, any member of the Immediate Family of any VGP Owner or any Estate Planning Entities.

 

5


Section 1.02. Interpretation. The words “herein,” “hereof’ and “hereunder” and other words of similar import refer to this Agreement as a whole, and not to any particular Article, Section, subsection or clause hereof. References herein to an Exhibit, Article, Section, subsection or clause refer to the appropriate Exhibit, Article, Section, subsection or clause hereof. Any Schedule, Exhibit or other attachment to this Agreement shall be incorporated into this Agreement, and made a part of this Agreement for all purposes, unless the context otherwise requires. Any definition of or reference to any agreement, instrument, other document, schedule, exhibit, statute, law or regulation herein shall be construed as referring to such agreement, instrument, other document, schedule, exhibit, statute, law or regulation as from time to time amended, supplemented, restated or otherwise modified. Any reference herein to any Person shall include its heirs, successors and permitted assigns and, in the case of any Governmental Authority, any Person succeeding to its functions and capacities. Any reference herein to days shall refer to calendar days unless Business Days are specified; references to weeks, months or years shall be to calendar weeks, months or years, respectively. All accounting terms used herein and not otherwise defined will have the meanings accorded them under GAAP and, except as expressly provided herein, all accounting determinations will be made in accordance with such accounting principles in effect from time to time. Any reference to “include” or “including” shall be treated as “including, without limitation”. Defined terms in the singular shall include the plural and vice versa, and the masculine, feminine or neuter gender shall include all genders. No consideration shall be given to the fact or presumption that any Party had a greater or lesser hand in drafting this Agreement.

ARTICLE II

REGISTRATION RIGHTS

Section 2.01. Registration Rights.

(a) Piggyback Registration Rights.

(i) If the Corporation proposes to register (including, for this purpose, a registration effected by the Corporation for any stockholders other than Holders) any of its Equity Securities that may include Class A Common Shares under the Securities Act in connection with a public offering of such securities for cash at any time after the consummation of the IPO (other than in an Excluded Registration), the Corporation shall, at such time, promptly give each Holder notice of such registration at least seven (7) days prior to the filing of any registration statement for such offering.

(ii) [Reserved.]

(iii) Upon the Holder’s written request (which must be provided to the Corporation within seven (7) days after such notice pursuant to Section 2.01(a)(i) is given by the Corporation), the Corporation shall, subject to the provisions of Section 2.01(c), include in such registration all Registrable Securities that are requested by such Holder (such registration, a “Piggyback Registration”).

 

6


(iv) The Corporation shall have the right to terminate or withdraw any Piggyback Registration initiated by it before the effective date of the applicable registration statement or the filing of a prospectus or supplement relating to the applicable offering, as the case may be, whether or not any other Holder has elected to include such Holder’s Registrable Securities in such registration. The expenses of such withdrawn registration shall be borne solely by the Corporation.

(v) If a Piggyback Registration involves an underwritten offering on behalf of the Corporation and the total number of Registrable Securities requested by Holders to be included in such offering exceeds the number of securities which can be sold (other than by the Corporation) that the managing underwriter and the Corporation in their reasonable discretion determine would not impact the pricing of the offering, then the Corporation shall be entitled to reduce the number of Registrable Securities included in such Piggyback Registration to the number that the managing underwriter and the Corporation in their reasonable discretion determine can be sold without having the impact on pricing referred to above, and the number of Registrable Securities registered shall be allocated in the following priority: (i) first, the number of Equity Securities that the Corporation proposes to sell and (ii) second, the number of Registrable Securities requested to be included therein by Holders, allocated pro rata among all such Holders on the basis of the number of Registrable Securities then outstanding owned by each such Holder or in such manner as they may otherwise agree. If, as a result of the provisions of this Section 2.01(a)(v), any Holder shall not be entitled to include all Registrable Securities in a Piggyback Registration that such Holder has requested be included, such Holder may elect to withdraw its Registrable Securities from such Piggyback Registration.

(b) Demand Registration Rights.

(i) If at any time after one hundred eighty (180) days after the effective date of the registration statement for the IPO the Corporation receives a request (a “Demand Request”) from the then-current Holders of at least five percent (5%) of the aggregate number of Registrable Securities then outstanding that the Corporation file a Form S-1 registration statement (or, if eligible, a Form S-3 registration statement) with respect to outstanding Registrable Securities of such Holders having an anticipated aggregate offering price, net of underwriting discounts and commissions, of at least $100 million, then (A) the Corporation shall, within ten (10) days after the date such request is given, give notice thereof (the “Demand Notice”) to all Holders other than the Initiating Holders, and (B) the Corporation shall use its commercially reasonable efforts to, as soon as practicable, and in any event within sixty (60) days (or, if eligible to use a Form S-3 registration statement, within sixty (60) days) after the date such Demand Request is given by the Initiating Holders, file a Form S-1 registration statement or Form S-3 registration statement, as applicable, under the Securities Act covering all Registrable Securities that the Initiating Holders requested to be registered and any additional Registrable Securities requested to be included in such registration by any other Holders as specified by notice given by each such

 

7


Holder to the Corporation within twenty (20) days of the date the Demand Notice is given, and in each case subject to the limitations set forth in this Section 2.01, which may provide for an offering of such Registrable Securities to be made on a delayed or continuous basis pursuant to Rule 415 under the Securities Act (or any successor or similar rule) (a “Shelf Registration”).

(ii) Any of the then-current Holders of at least five percent (5%) of the aggregate number of Registrable Securities then outstanding may request an underwritten offering using any existing and effective Shelf Registration (an “Underwritten Takedown”), and any such request shall be deemed a Demand Registration. Following any such request, the Corporation shall (A) within ten (10) days after the date such request is given, give notice thereof to all other Holders, (B) use its commercially reasonable efforts to, as soon as practicable, amend or supplement the Shelf Registration as may be reasonably necessary to facilitate the Underwritten Takedown, and (C) subject to Section 2.01(b)(iv), include in such Underwritten Takedown all such Registrable Securities with respect to which the Corporation has received written requests for inclusion therein within five (5) days after the Corporation’s giving of such notice; provided, however, that such Registrable Securities (i) are covered by an existing and effective Shelf Registration that may be utilized for the offering and sale of the Registrable Securities requested to be included or (ii) may be included in such Shelf Registration without the need for a post-effective amendment to such Shelf Registration (other than an automatically effective amendment). Notwithstanding the foregoing, the Corporation shall not be required to effect such Underwritten Takedown, and such request shall not be deemed to have been made, unless the anticipated aggregate offering price, net of underwriting discounts and commissions, of the securities being offered is at least $100 million. The provisions of this Section 2.01(b) shall apply mutatis mutandis to each Underwritten Takedown, with references to “filing of a registration statement” or such registration statement being declared “effective” being deemed references to filing of a prospectus or supplement for such offering and references to “registration” being deemed references to the offering.

(iii) Any of the then-current Holders of at least five percent (5%) of the aggregate number of Registrable Securities then outstanding may initiate an Underwritten Takedown that is a Block Trade using any existing and effective Shelf Registration (an “Underwritten Block Trade”) by notice to the Corporation (an “Underwritten Block Trade Notice”) at least five (5) days prior to the requested commencement of such Underwritten Block Trade, and any such request shall be deemed a Demand Registration. Following any such request, the Corporation shall (A) as promptly as practicable after receiving such Underwritten Block Trade Notice, notify all Holders of Registrable Securities of its receipt of an Underwritten Block Trade Notice, (B) use its commercially reasonable efforts to facilitate such Underwritten Block Trade as expeditiously as possible, and (C) subject to Section 2.01(b)(iv), include in such Underwritten Block Trade all such Registrable Securities with respect to which the Corporation has received written requests for inclusion therein within one (1) Business Day

 

8


after the Corporation’s giving of such notice; provided that such Registrable Securities requested by Holders to be included in such Underwritten Block Trade (i) are covered by an existing and effective Shelf Registration that may be utilized for the offering and sale of the Registrable Securities requested to be included or (ii) may be included in such Shelf Registration without the need for a post-effective amendment to such Shelf Registration (other than an automatically effective amendment), and provided further that the Initiating Holders shall use commercially reasonable efforts to work with the Corporation and the underwriters prior to making such request in order to facilitate preparation of the registration statement, prospectus and other offering documentation related to the Underwritten Block Trade. Notwithstanding the foregoing, the Corporation shall not be required to effect such Underwritten Block Trade, and such request shall not be deemed to have been made, unless the anticipated aggregate offering price, net of underwriting discounts and commissions, of the securities being offered is at least $100 million. The provisions of this Section 2.01(b) shall apply mutatis mutandis to each Underwritten Block Trade, with references to “filing of a registration statement” or such registration statement being declared “effective” being deemed references to filing of a prospectus or supplement for such offering and references to “registration” being deemed references to the offering.

(iv) If a Demand Registration involves an underwritten offering, including an Underwritten Takedown or an Underwritten Block Trade, and the Registrable Securities requested by Holders to be included in such offering exceeds the number of securities which can be sold that the managing underwriter and the Corporation in their reasonable discretion determine would not impact the pricing of the offering, then the Corporation shall be entitled to reduce the number of Registrable Securities included in such Demand Registration to the number that the managing underwriter and the Corporation in their reasonable discretion determine can be sold without having the impact on pricing referred to above, and the number of Registrable Securities registered shall be allocated pro rata among such Holders on the basis of the total number of Registrable Securities owned by such Holders or in such manner as they may otherwise agree; provided that the number of Registrable Securities held by such Holders to be included in such underwriting shall not be reduced unless all securities other than Registrable Securities held by any Holders are first excluded from such offering.

(v) Notwithstanding the foregoing obligations, if the Corporation furnishes to Holders requesting a registration pursuant to this Section 2.01(b) a certificate signed by the Corporation’s chief executive officer stating that in the good faith judgment of the Board of Directors it would be materially detrimental to the Corporation and its stockholders for such registration statement to either become effective or remain effective for as long as such registration statement otherwise would be required to remain effective, because such action would (A) materially interfere with a significant acquisition, corporate reorganization, strategic matter, or other similar transaction or matter involving the Corporation or its subsidiaries or affiliates, (B) require premature disclosure of material information that the Corporation has a bona fide business purpose for preserving

 

9


as confidential, or (C) render the Corporation unable to comply with requirements under the Securities Act or Exchange Act, then the Corporation shall have the right to (i) defer taking action with respect to such filing (and any time periods with respect to filing or effectiveness thereof shall be tolled correspondingly) and (ii) suspend the use of the such registration statement (and any time periods with respect to such suspension shall be tolled correspondingly), in each case for a period of not more than one hundred twenty (120) days after the request of the Initiating Holders is given; provided that the Corporation may not invoke this right more than twice in any twelve (12)-month period.

(vi) The Corporation shall not be obligated to effect, or to take any action to effect, any Demand Registration, including any Underwritten Takedown or Underwritten Block Trade, (A) during the period that is one hundred twenty (120) days before the Corporation’s good faith estimate of the date of filing of a registration statement for a primary offering of any securities by the Corporation, (B) during any period of one hundred eighty (180) days following the closing or completion of an offering of any securities by the Corporation, (C) within one hundred eighty (180) days of the effective date of any registration pursuant to Section 2.01(b)(i), an Underwritten Takedown pursuant to Section 2.01(b)(ii) or an Underwritten Block Trade pursuant to Section 2.01(b)(iii), or (D) if a Piggyback Registration pursuant to Section 2.01(a) had been available within the one hundred eighty (180) days preceding the date of the Demand Request (whether or not any Holder elected to include any Registrable Securities in such registration). Furthermore, the Corporation shall not be obligated to effect, or to take any action to effect, more than one (1) Demand Registration in any twelve (12)-month period until the third anniversary of the effective date of the registration statement for the IPO, and more than two (2) Demand Registrations in any twelve (12)-month period thereafter. A registration shall not be counted as “effected” for purposes of this Section 2.01(b)(v) until such time as the applicable registration statement has been declared effective by the SEC.

(vii) Whenever required under this Section 2.01(b) to effect the registration of any Registrable Securities, the Corporation shall, as expeditiously as reasonably possible:

(A) prepare and file with the SEC a registration statement with respect to such Registrable Securities and use its commercially reasonable efforts to cause such registration statement to become effective and, upon the request of the Holders of a majority of the Registrable Securities registered thereunder, keep such registration statement effective for a period of up to thirty (30) days or, if earlier, until the distribution contemplated in the registration statement has been completed; provided that such thirty (30) day period shall be extended for a period of time equal to the period the Holder refrains, at the request of an underwriter of the applicable securities of the Corporation, from selling any securities included in such registration;

 

10


(B) furnish to the selling Holders such numbers of copies of a prospectus, including a preliminary prospectus, as required by the Securities Act in order to facilitate their disposition of their Registrable Securities;

(C) use its commercially reasonable efforts to register and qualify the securities covered by such registration statement under such other securities or blue-sky laws of such jurisdictions as shall be reasonably requested by the selling Holders; provided that the Corporation shall not be required to qualify to do business or to file a general consent to service of process in any such states or jurisdictions, unless the Corporation is already subject to service in such jurisdiction and except as may be required by the Securities Act;

(D) prepare and file with the SEC such amendments and supplements to such registration statement, and the prospectus used in connection with such registration statement, as may be necessary to comply with the Securities Act in order to enable the disposition of all securities covered by such registration statement;

(E) in the event of any underwritten public offering, enter into and perform its obligations under an underwriting agreement, in usual and customary form, with the underwriter(s) of such offering;

(F) use its commercially reasonable efforts to cause all such Registrable Securities covered by such registration statement to be listed on a national securities exchange or trading system and each securities exchange and trading system (if any) on which similar securities issued by the Corporation are then listed;

(G) promptly make available for inspection by any managing underwriter participating in any disposition pursuant to such registration statement all financial and other records, pertinent corporate documents, and properties of the Corporation, and cause the Corporation’s officers, directors, employees, and independent accountants to supply all information reasonably requested by any such underwriter as reasonably necessary or advisable to verify the accuracy of the information in such registration statement and to conduct appropriate due diligence in connection therewith;

(H) notify each selling Holder, promptly after the Corporation receives notice thereof, of the time when such registration statement has been declared effective or a supplement to any prospectus forming a part of such registration statement has been filed; and

 

11


(I) after such registration statement becomes effective, notify each selling Holder and the managing underwriter, if any, (1) of any request by the SEC that the Corporation amend or supplement such registration statement or prospectus, (2) the SEC issues any stop order suspending the effectiveness of such registration statement or initiates any proceedings for that purpose, (3) the discovery of any event which requires that any changes be made in such registration statement or any related prospectus so that such registration statement or prospectus will not contain any untrue statement of a material fact or omit to state any material fact required to be stated therein or necessary to make the statements therein not misleading, in light of the circumstances under which they were made (provided, however, that, in the case of this subclause (3), such notice need only state that an event of such nature has occurred, without describing such event), or (4) of the determination by counsel of the Corporation that a post-effective amendment to such registration statement (including any amendment or supplement thereto) is advisable, and the Corporation shall promptly use its commercially reasonable efforts to make any such required filings, amendments or supplements or to obtain the withdrawal or any such stop or similar order.

(c) It shall be a condition precedent to the obligations of the Corporation to take any action pursuant to this Section 2.01 with respect to the Registrable Securities of any selling Holder that such Holder shall furnish to the Corporation such information regarding itself, the Registrable Securities held by it, and the intended method of disposition of such securities as is reasonably required to effect the registration of such Holder’s Registrable Securities.

(d) In connection with any offering involving an underwriting of the Corporation’s Equity Securities pursuant to this Section 2.01, whether initiated by the Corporation, any Holder or otherwise, (i) the underwriter(s) for such offering shall be selected by the Corporation, and (ii) the Corporation shall not be required to include any Registrable Securities for any Holder in such underwriting unless such Holder (A) agrees to sell its Registrable Securities on the basis provided in any underwriting arrangements as agreed upon between the Corporation and its underwriters, and (B) completes and executes all questionnaires, powers of attorney, indemnities, underwriting agreements and other documents reasonably required under the terms of such underwriting arrangements; provided, that, except as required by Section 2.01(h), no Holder included in any underwritten registration shall be required to make any representations or warranties to the Corporation or the underwriters (other than representations and warranties regarding such Holder, such Holder’s ownership of its Registrable Securities to be sold in the offering and such Holder’s intended method of distribution) or to undertake any indemnification obligations to the Corporation or the underwriters with respect thereto.

(e) To facilitate the allocation of Registrable Securities in accordance with Section 2.01(a)(v) or Section 2.01(b)(iv), the Corporation or the underwriters may round the number of shares allocated to any Holder to the nearest 10 Shares. For purposes of the provisions in this Section 2.01 concerning apportionment, for any selling Holder that is a partnership, limited liability company, or corporation, the partners, members, retired

 

12


partners, retired members, stockholders, and Affiliates of such Holder, or the estates and Immediate Family of any such partners, retired partners, members, and retired members and any trusts for the benefit of any of the foregoing Persons, shall be deemed to be a single “selling Holder,” and any pro rata reduction with respect to such “selling Holder” shall be based upon the aggregate number of Registrable Securities owned by all Persons included in such “selling Holder,” as defined in this sentence.

(f) Each Holder shall, upon receipt of any notice from the Corporation of the happening of any event of the kind described in Section 2.01(b)(vii)(I), suspend the disposition of any Registrable Securities covered by such registration statement or prospectus (or any amendment or supplement thereto) until such Holder’s receipt of the copies of a supplemented or amended registration statement or prospectus, or until it is advised in writing by the Corporation that the use of the applicable registration statement or prospectus may be resumed. If the Corporation shall have given any such notice during a period when a Demand Registration is in effect, the period during which the Corporation is required to keep such registration effective pursuant to Section 2.01(b) shall be extended by the number of days of such suspension period.

(g) All expenses (other than underwriting discounts or selling commissions) incurred by the Corporation in complying with its obligations pursuant to this Section 2.01 and in connection with the registration and disposition of Registrable Securities, including, without limitation, all registration and filing fees, underwriting expenses (other than fees, commissions or discounts), expenses of any audits incident to or required by any such registration, fees and expenses of complying with securities and “blue sky” laws, printing expenses, fees and expenses of the Corporation’s counsel and accountants, and the reasonable and documented fees and expenses of one counsel for the selling Holders participating in such registration as a group (selected by the selling Holders of a majority of the Registrable Securities included in the registration), shall be paid by the Corporation.

(h) If any Registrable Securities are included in a registration statement under this Section 2.01:

(i) The Corporation shall indemnify and hold harmless, to the fullest extent permitted by law, each selling Holder participating in such registration, such Holder’s officers, directors, managers, members, partners, stockholders and Affiliates, any underwriter for each such Holder and each other Person, if any, who controls any such Holder or underwriter within the meaning of Section 15 of the Securities Act or Section 20 of the Exchange Act, against all losses, claims, actions, damages, liabilities and expenses, joint or several, to which any of the foregoing Persons may become subject under the Securities Act or otherwise, insofar as such losses, claims, actions, damages, liabilities or expenses arise out of or are based upon any untrue or alleged untrue statement of a material fact contained in any registration statement, prospectus, preliminary prospectus, free writing prospectus (as defined in Rule 405 promulgated under the Securities Act) or any amendment thereof or supplement thereto or any omission or alleged omission of a material fact required to be stated therein or necessary to make the

 

13


statements therein, in the light of the circumstances under which they were made, not misleading; and shall reimburse such Persons for any legal or other expenses reasonably incurred by any of them in connection with investigating or defending any such loss, claim, action, damage or liability; in each case, except insofar as such losses, claims, actions, damages, liabilities or expenses arise out of or are based upon any such untrue statement or omission made in reliance upon and in conformity with, as applicable, the written information relating to such selling Holder expressly for use therein.

(ii) Each selling Holder participating in such registration shall furnish to the Corporation in writing such information and affidavits relating to such Holder as the Corporation reasonably requests for use in connection with any such registration statement or prospectus and, to the extent permitted by law, shall indemnify and hold harmless, the Corporation, each director of the Corporation, each officer of the Corporation who shall sign such registration statement, any underwriter and each Person who controls the Corporation within the meaning of Section 15 of the Securities Act or Section 20 of the Exchange Act, against all losses, claims, actions, damages, liabilities or expenses, joint or several, to which any of the foregoing Persons may become subject und der the Securities Act or otherwise, insofar as such losses, claims, actions, damages, liabilities or expenses arise out of or are based upon any untrue or alleged untrue statement of a material fact contained in any registration statement, prospectus, preliminary prospectus, free writing prospectus (as defined in Rule 405 promulgated under the Securities Act) or any amendment thereof or supplement thereto or any omission or alleged omission of a material fact required to be stated therein or necessary to make the statements therein, in the light of the circumstances under which they were made, not misleading, but only to the extent that such untrue statement or omission is contained in any information or affidavit so furnished in writing by such Holder; and shall reimburse such Persons for any legal or other expenses reasonably incurred by any of them in connection with investigating or defending any such loss, claim, action, damage or liability; provided, that the obligation to indemnify and reimburse shall be several, not joint and several, for each Holder and shall be limited to the net proceeds (after underwriting fees, commissions or discounts) actually received by such Holder from the sale of Shares pursuant to such registration statement.

(iii) If the indemnification provided for hereunder is held by a court of competent jurisdiction to be unavailable to an indemnified party with respect to any loss, claim, damage, liability or action referred to herein, then the indemnifying party, in lieu of indemnifying such indemnified party hereunder, shall contribute to the amounts paid or payable by such indemnified party as a result of such loss, claim, damage, liability or action in such proportion as is appropriate to reflect the relative fault of the indemnifying party on the one hand and of the indemnified party on the other in connection with the statements or omissions which resulted in such loss, claim, damage, liability or action as well as any other relevant equitable considerations; provided, that the maximum amount of liability in respect of such contribution shall be limited, in the case of each

 

14


Holder, to an amount equal to the net proceeds (after underwriting fees, commissions or discounts) actually received by such seller from the sale of Shares effected pursuant to such registration. The relative fault of the indemnifying party and of the indemnified party shall be determined by reference to, among other things, whether the untrue or alleged untrue statement of a material fact or the omission or alleged omission to state a material fact relates to information supplied by the indemnifying party or by the indemnified party and the parties’ relative intent, knowledge, access to information and opportunity to correct or prevent such statement or omission. The parties agree that it would not be just and equitable if contribution pursuant hereto were determined by pro rata allocation or by any other method or allocation which does not take account of the equitable considerations referred to herein. No Person guilty or liable of fraudulent misrepresentation shall be entitled to contribution from any Person.

(iv) Promptly after receipt by an indemnified party under this Section 2.01(h) of notice of the commencement of any action (including any governmental action) for which a party may be entitled to indemnification hereunder, such indemnified party will, if a claim in respect thereof is to be made against any indemnifying party under this Section 2.01(h), give the indemnifying party notice of the commencement thereof. The indemnifying party shall have the right to participate in such action and, to the extent the indemnifying party so desires, participate jointly with any other indemnifying party to which notice has been given, and to assume the defense thereof with counsel mutually satisfactory to the parties; provided, however, that an indemnified party (together with all other indemnified parties that may be represented without conflict by one counsel) shall have the right to retain one separate counsel, with the fees and expenses to be paid by the indemnifying party, if representation of such indemnified party by the counsel retained by the indemnifying party would be inappropriate due to actual or potential differing interests between such indemnified party and any other party represented by such counsel in such action. The failure to give notice to the indemnifying party within a reasonable time of the commencement of any such action shall not relieve such indemnifying party of any liability to the indemnified party under this Section 2.01(h), except to the extent that such failure materially prejudices the indemnifying party’s ability to defend such action. The failure to give notice to the indemnifying party will not relieve it of any liability that it may have to any indemnified party otherwise than under this Section 2.01(h).

(v) Notwithstanding the foregoing, to the extent that the provisions on indemnification and contribution contained in any underwriting agreement entered into in connection with the applicable offering are in conflict with the foregoing provisions, the provisions in such underwriting agreement shall control.

(vi) Unless otherwise superseded by an underwriting agreement entered into in connection with the applicable offering, the obligations of the Corporation and Holders under this Section 2.01(h) shall survive the completion of any offering of Registrable Securities in a registration under this Section 2.01, and otherwise shall survive the termination of this Agreement or any provision(s) of this Agreement.

 

15


(i) No Holder shall have any right to obtain or seek an injunction restraining or otherwise delaying any registration pursuant to this Agreement as the result of any controversy that might arise with respect to the interpretation or implementation of this Section 2.01.

(j) The Corporation shall not, without the prior written consent of the Holders of a majority of the Registrable Securities then outstanding, (i) enter into any agreement with any holder or prospective holder of any securities of the Corporation that would allow such holder or prospective holder to include such securities in any registration unless, under the terms of such agreement, such holder or prospective holder may include such securities in any such registration only to the extent that the inclusion of such securities will not reduce the number of the Registrable Securities of the Holders that are included, or (ii) enter into any agreement, take any action, or permit any change to occur, with respect to its securities that violates or subordinates the rights expressly granted to the Holders in this Section 2.01.

Section 2.02. Legends.

(a) Each certificate, instrument, or book entry representing (i) the Registrable Securities and (ii) any other securities issued in respect of the securities referenced in clause (i), upon any stock split, stock dividend, recapitalization, merger, consolidation, or similar event, shall be notated with a legend substantially in the following form:

THE SECURITIES REPRESENTED HEREBY HAVE BEEN ACQUIRED FOR INVESTMENT AND HAVE NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933. SUCH SHARES MAY NOT BE SOLD, PLEDGED, OR TRANSFERRED IN THE ABSENCE OF SUCH REGISTRATION OR A VALID EXEMPTION FROM THE REGISTRATION AND PROSPECTUS DELIVERY REQUIREMENTS OF SAID ACT.

THE SECURITIES REPRESENTED HEREBY MAY BE TRANSFERRED ONLY IN ACCORDANCE WITH THE TERMS OF AN AGREEMENT BETWEEN THE COMPANY AND THE STOCKHOLDER, A COPY OF WHICH IS ON FILE WITH THE SECRETARY OF THE COMPANY.

The Holders consent to the Corporation making a notation in its records and giving instructions to any transfer agent of the Registrable Securities in order to implement the restrictions on transfer set forth in this Section 2.02(a).

 

16


(b) The holder of securities of the Corporation required to be notated with the legend in Section 2.02(a) (“Restricted Securities”), by acceptance of ownership thereof, agrees to comply in all respects with the provisions of this Section 2.02(b). Before any proposed sale, pledge, or transfer of any Restricted Securities, unless there is in effect a registration statement under the Securities Act covering the proposed transaction, the holder thereof shall give notice to the Corporation of such holder’s intention to effect such sale, pledge, or transfer, provided that no such notice shall be required if the intended sale, pledge or transfer complies with Rule 144. Each such notice shall describe the manner and circumstances of the proposed sale, pledge, or transfer in sufficient detail and, if reasonably requested by the Corporation, shall be accompanied at such holder’s expense by either (i) a written opinion of legal counsel who shall, and whose legal opinion shall, be reasonably satisfactory to the Corporation, addressed to the Corporation, to the effect that the proposed transaction may be effected without registration under the Securities Act, (ii) a “no action” letter from the SEC to the effect that the proposed sale, pledge, or transfer of such Restricted Securities without registration will not result in a recommendation by the staff of the SEC that action be taken with respect thereto, or (iii) any other evidence reasonably satisfactory to counsel to the Corporation to the effect that the proposed sale, pledge, or transfer of the Restricted Securities may be effected without registration under the Securities Act, whereupon the holder of such Restricted Securities shall be entitled to sell, pledge, or transfer such Restricted Securities in accordance with the terms of the notice given by the holder to the Corporation. The Corporation will not require such a notice, legal opinion or “no action” letter (x) in any transaction in compliance with Rule 144, or (y) in any transaction in which such holder distributes Restricted Securities to an Affiliate of such holder for no consideration; provided that with respect to transfers under the foregoing clause (y), each transferee agrees in writing to be subject to the terms of this Section 2.02(b). Each certificate, instrument, or book entry representing Restricted Securities transferred as above provided shall be notated with, except if such transfer is made pursuant to Rule 144, the appropriate restrictive legend set forth above, except that such certificate, instrument, or book entry shall not be notated with such restrictive legend if, in the opinion of counsel for such holder and the Corporation, such legend is not required in order to establish compliance with any provisions of the Securities Act.

Section 2.03. Public Offering Lock-Up. Each Shareholder hereby agrees that, in connection with any underwritten public offering (including the IPO) (any such offering, “Public Offering”), it will not, without the prior written consent of the managing underwriter(s) of such Public Offering), (or, if applicable, such subset of managing underwriter(s) as may be selected by the Corporation, during the period commencing on the date that a preliminary prospectus relating to such Public Offering is first circulated and continuing to the date that is (1) in the case of the IPO, one hundred eighty (180) days following the date of the final prospectus relating to the IPO, or (2) in the case of any other such Public Offering, ninety (90) days following the date of the final prospectus relating to such Public Offering (or such shorter period as the managing underwriter(s) for such Public Offering may agree to), in each case (i) lend; offer; pledge; sell; contract to sell; sell any option or contract to purchase; purchase any option or contract to sell; grant any option, right, or warrant to purchase; or otherwise transfer or dispose of, directly or indirectly, any Class A Common Shares or any securities convertible into or exercisable or exchangeable (directly or indirectly) for Class A Common Shares, (ii) enter into any hedge, swap or other arrangement that transfers to

 

17


another, in whole or in part, any of the economic consequences of ownership of such securities, whether any such transaction described in clause (i) or (ii) above is to be settled by delivery of Class A Common Shares or other securities, in cash, or otherwise, or (iii) publicly disclose the intention to enter into any such transaction described in clause (i) or (ii) above. The foregoing provisions of this Section 2.03 (i) shall not apply to (a) the sale of any Class A Common Shares to an underwriter pursuant to an underwriting agreement relating to the applicable Public Offering, (b) the establishment of a trading plan pursuant to Rule 10b5-1, provided that such plan does not permit transfers during the applicable restricted period, (c) the transfer of any Class A Common Shares to any trust for the direct or indirect benefit of the Shareholder or the Immediate Family of the Shareholder, provided that the trustee of the trust agrees to be bound in writing by the restrictions set forth in this Section 2.03, and provided further that any such transfer shall not involve a disposition for value, (d) to the extent the Shareholder is a corporation, partnership, limited liability company, or other business entity, transfers, distributions or dispositions (x) to limited partners, members, stockholders or holders of similar equity interests in the Shareholder or (y) to another corporation, partnership, limited liability company, trust or other business entity that is an Affiliate of the Shareholder, or to any investment fund or other entity controlled or managed by the Shareholder or Affiliates of the Shareholder, provided that the transferee agrees to be bound in writing by the restrictions set forth in this Section 2.03, (e) securities of the Corporation acquired in the applicable Public Offering or in open-market or privately negotiated transactions after the completion of the applicable Public Offering, (f) the transfer of securities of the Corporation pursuant to a bona fide third party tender offer, merger, consolidation or other similar transaction made to all holders of the capital stock of the Corporation involving a change of control of the Corporation which occurs after the consummation of the applicable Public Offering, is open to all holders of the capital stock of the Corporation and has been approved by the Board of Directors or (g) transfers of Class A Common Shares pursuant to a final non-appealable order of a court or regulatory agency, (ii) shall be subject to other customary exceptions, the nature of those exceptions to be determined by the Corporation acting reasonably after taking into account advice received from the underwriters in the applicable Public Offering and (iii) shall be applicable to the Shareholders only if all officers and directors of the Corporation are subject to the same restrictions. The underwriters in the applicable Public Offering are intended third-party beneficiaries of this Section 2.03 and shall have the right, power and authority to enforce the provisions hereof as though they were a party hereto. Each Shareholder further agrees to execute such agreements as may be reasonably requested by the underwriters in the applicable Public Offering that are consistent with this Section 2.03 or that are necessary to give further effect thereto. The Shareholders also agree and consent to the entry of stop transfer instructions with the Corporation’s transfer agent and registrar against the transfer of their respective Class A Common Shares except in compliance with the foregoing restrictions. Notwithstanding anything to the contrary in this Agreement, the exercise of any registration rights pursuant to this Agreement shall be subject to the restrictions set forth in this Section 2.03(b).

 

18


ARTICLE III

TERM; TERMINATION

Section 3.01. Termination. This Agreement shall terminate on the earliest to occur of: (i) termination by written consent of each of the Corporation, the Holders holding a majority of the Shares held by all Holders and the Holders holding a majority of the Shares not held by VGP and the VGP Related Persons, (ii) the date on which no Registrable Securities remain outstanding, and (iii) the final dissolution and completion or winding up of the Corporation.

ARTICLE IV

GENERAL PROVISIONS

Section 4.01. Notices. All notices, requests, or consents provided for or permitted to be given under this Agreement must be in writing and must be given by delivering that writing to the recipient in person, by courier, by electronic mail, or by facsimile transmission; and a notice, request, or consent given under this Agreement is effective on receipt by the Person to receive it; provided, however, that a facsimile or electronic mail that is transmitted after the normal business hours of the recipient shall be deemed effective on the next Business Day. All notices, requests, and consents to be sent to a Holder must be sent to or made at the addresses given for that Holder on Exhibit A or in the Accession Agreement for such Holder, as the case may be, or such other address as that Holder may specify by notice to the Corporation and the other Holders. All notices, requests, and consents to be sent to the Corporation must be sent to or made at the following address:

Venture Global, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

Email: [  ], [  ]

Section 4.02. Entire Agreement. This Agreement constitutes the entire agreement and understanding of the Parties hereto in respect of its subject matters and supersedes all prior understandings, agreements, or representations by or among such Parties, written or oral, to the extent they relate in any way to the subject matter of this Agreement or the transactions contemplated by this Agreement and/or the Original Agreement. There are no side letters between or among the Corporation and any Institutional Holder related to the subject matter set forth in this Agreement.

Section 4.03. Successors and Assigns. This Agreement shall be binding upon and inure to the benefit of the Holders and their respective successors and permitted assigns.

 

19


Section 4.04. Governing Law. THIS AGREEMENT AND THE PERFORMANCE OF THE TRANSACTIONS AND THE OBLIGATIONS OF THE PARTIES HEREUNDER WILL BE GOVERNED BY AND CONSTRUED AND ENFORCED IN ACCORDANCE WITH THE LAWS OF THE STATE OF DELAWARE, WITHOUT GIVING EFFECT TO ANY CHOICE OF LAW PRINCIPLES.

Section 4.05. Jurisdiction and Venue. IN RESPECT OF ANY ACTION OR PROCEEDING ARISING OUT OF OR RELATING TO THIS AGREEMENT, EACH OF THE PARTIES HERETO CONSENTS TO THE JURISDICTION AND VENUE OF ANY FEDERAL OR STATE COURT LOCATED WITHIN THE SOUTHERN DISTRICT OF NEW YORK, AND WAIVES ANY MOTION TO TRANSFER VENUE FROM, ANY OF THE AFORESAID COURTS.

Section 4.06. Waiver of Jury Trial. THE PARTIES HERETO WAIVE ALL RIGHT TO TRIAL BY JURY IN ANY ACTION OR PROCEEDING TO ENFORCE OR DEFEND ANY RIGHTS UNDER THIS AGREEMENT AND ANY DOCUMENT EXECUTED IN CONNECTION HEREWITH.

Section 4.07. Severability. If any provision of this Agreement is held to be unenforceable, this Agreement shall be considered divisible and such provision shall be deemed inoperative to the extent it is deemed unenforceable, and in all other respects this Agreement shall remain in full force and effect; provided, however, that if any provision may be made enforceable by limitation thereof, then such provision shall be deemed to be so limited and shall be enforceable to the maximum extent permitted by Applicable Law.

Section 4.08. No Third Party Beneficiaries. Except as otherwise provided in Section 2.03 and for the indemnification rights of the any Holder or the Corporation under this Agreement, it is the intent of the Parties hereto that no third-party beneficiary rights be created or deemed to exist in favor of any Person not a party to this Agreement, unless otherwise expressly agreed to in writing by the parties.

Section 4.09. Joinder of Additional Holders. The rights of each Holder under this Agreement may be assigned (but only with all related obligations) in connection with a disposition of Registrable Securities to an Affiliate of such Holder (or, in the case of the Management Holder, to any VGP Related Person), upon the execution of an Accession Agreement.

Section 4.10. Counterparts. This Agreement may be executed in any number of counterparts, with each such counterpart constituting an original and all of such counterparts constituting but one and the same instrument. Counterparts may be delivered via facsimile, electronic mail (including any electronic signature covered by the U.S. federal ESIGN Act of 2000, Uniform Electronic Transactions Act, the Electronic Signatures and Records Act or other Applicable Law, e.g., www.docusign.com) or other transmission method and any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

 

20


Section 4.11. Confidentiality. During the term of this Agreement and thereafter, each party hereto will, and will cause each of its Representatives (defined below) to, keep confidential all non-public information received from or otherwise relating to the Corporation or its subsidiaries, properties and businesses (including any notice of the Corporation’s intention or plan to confidentially submit or file a registration statement, any Demand Notice, any Demand Request, any Underwritten Block Trade Notice or any other notice hereunder and, in each case, the information contained herein) (“Confidential Information”) and will not, and will not permit its Representatives to, (a) disclose Confidential Information to any other Person other than (i) to another party hereto for a valid business purpose of the Corporation, (ii) in the case of Persons who are also officers, agents or representatives of the Corporation, in carrying out their duties in the best interests of the Corporation, or (iii) any potential bona fide transferee of a Holder’s Shares; provided that such potential transferee agrees to maintain the confidentiality of the Confidential Information on terms no less restrictive than those set forth in this Section 4.11 or (b) use Confidential Information for anything other than as necessary and appropriate in carrying out the business of the Corporation. The restrictions set forth in this Section 4.11 do not apply to any disclosures relating to U.S. federal and state income tax treatment and tax structure of the transaction contemplated hereby and all materials of any kind (including opinions and tax analyses) relating to the tax treatment and tax structure, not including information relating to the identity of the Holders, their respective Affiliates, agents, or advisors. As used herein the term “Confidential Information” shall not include information that (i) is, was, or becomes generally available to the public other than as a result of a disclosure by a party hereto, or its Affiliates, partners, directors, managers, officers, employees, agents, counsel, investment advisers or representatives or to such party’s designees on the Board of Directors or any board observers appointed by such party (all such Persons being collectively referred to as “Representatives”) in violation of this Agreement, (ii) is or was available to such party on a non-confidential basis prior to its disclosure to such party or its Representatives by the Corporation, (iii) is, was or becomes available to such party on a non- confidential basis from a source other than the Corporation, which source represents that it had the right to disseminate such information at the time it was acquired by such party, (iv) is independently developed by such party or on such party’s behalf without reference to the Confidential Information, or (v) is requested or required to be disclosed by law, rule, regulation, or order of a court with competent jurisdiction, or judicial proceeding so long as the Person subject to such disclosure obligations provides prompt notice (to the extent reasonably practicable) to the Corporation stating the basis upon which the disclosure is asserted to be required. The Holders agree that irreparable damage would occur in the event that any of the provisions of this Section 4.11 were not to be performed in accordance with the terms hereof and that (a) the Corporation and (b) the Holders shall be entitled to specific performance of the terms hereof in addition to any other remedy available at law or in equity.

Section 4.12. Amendment and Waiver. Any term of this Agreement may be amended and the observance of any term hereof may be waived (either prospectively or retroactively and either generally or in a particular instance) with the written consent of (a) the Corporation, and (b) the Holders of a majority of the Registrable Securities then outstanding; provided, that any such amendment or waiver that would adversely and disproportionately affect one or more Institutional Holders’ rights under this Agreement (relative to the Management Holder) shall require the consent of the Lead Institutional Holder.

 

21


IN WITNESS WHEREOF, the Parties have duly executed this Shareholders’ Agreement as of the date first written above.

 

CORPORATION:

 

VENTURE GLOBAL, INC.

By:    
 

Name:

 

Title:

 

A-1


Date:               

HOLDER:

 

VENTURE GLOBAL PARTNERS II, LLC

 

Number of Class A Common

Shares held by the Holder: 435,500

    By:    
   

Name: Robert Pender

Title: Managing Partner

    By:    
      Name: Michael Sabel
      Title: Managing Partner

 

A-2


Exhibit A

Holders

 

HOLDER NAME

and

NOTICE INFORMATION

   Class A
Common Stock
(# of Shares)

Venture Global Partners II, LLC

 

Notice to:

Robert Pender

c/o Venture Global Partners, LLC

1101 30th Street, NW

Washington, DC 20007

Tel: 202-637-6814

Email: mender@ventureglobalgartners.com

   435,500

LVS III LP

 

Notice to:

Greg Kennedy

c/o Pacific Investment Management Company, LLC

650 Newport Center Drive

Newport Beach, CA 92660

   14,360

OC III LFE IV LP

 

Notice to:

Greg Kennedy

c/o Pacific Investment Management Company, LLC

650 Newport Center Drive

Newport Beach, CA 92660

   6,421

OC II LVS I LP

 

Notice to:

Greg Kennedy

c/o Pacific Investment Management Company, LLC

650 Newport Center Drive

Newport Beach, CA 92660

   19,252

PIMCO Dynamic Income Strategy Fund

 

Notice to:

Greg Kennedy

c/o Pacific Investment Management Company, LLC

650 Newport Center Drive

Newport Beach, CA 92660

   3,473

 

A-1


HOLDER NAME

and

NOTICE INFORMATION

   Class A
Common Stock
(# of Shares)

PIMCO Global Cross-asset Opportunities Fund Master Fund LDC

 

Notice to:

Greg Kennedy

c/o Pacific Investment Management Company, LLC

650 Newport Center Drive

Newport Beach, CA 92660

   14,423

PIMCO Red Stick Fund LP

 

Notice to:

Greg Kennedy

c/o Pacific Investment Management Company, LLC

650 Newport Center Drive

Newport Beach, CA 92660

   1,135

TOCU X LLC

 

Notice to:

Greg Kennedy

c/o Pacific Investment Management Company, LLC

650 Newport Center Drive

Newport Beach, CA 92660

   19,400

Luminus Energy Partners Master Fund LTD

 

Notice to:

Luminus Management LLC

Attn: Jonathan Barrett

1811 Bering Drive, Suite 400

Houston, TX 77057

   3,988

JM Cox Resources LP

 

Notice to:

4420 Amherst Avenue

Dallas, TX 75225

   1,401

Serengeti Opportunities MM LP

 

Notice to:

Attn: Operations Team

632 Broadway, 9th Floor

New York, NY 10012

   334

Mark H. McCormick Tr

 

Notice to:

974 Country Club Parkway

Castle Rock, CO 80108

   85

 

A-2


Exhibit B

ACCESSION AGREEMENT

This form of Accession Agreement (“Accession Agreement”) is executed on [  ], by the undersigned (the “New Holder”) pursuant to the terms of that certain Amended and Restated Shareholders’ Agreement dated as of [  ], [2024] (the “Agreement”), by and among Venture Global, Inc., a Delaware corporation (the “Corporation”), and the Holders party thereto, as may be amended and restated hereafter. Capitalized terms used but not defined in this Accession Agreement shall have the respective meanings ascribed to such terms in the Agreement. By the execution of this Accession Agreement, the New Holder agrees as follows.

1.1 Acknowledgement. The New Holder acknowledges that [he/she/it] is acquiring [  ] shares of Class A Common Shares and/or Class B Common Shares of the Corporation (the “Shares”); and after such acquisition, the New Holder shall be considered a “Holder” and a “Party” for all purposes of the Agreement.

1.2 Agreement. The New Holder hereby (a) agrees that the Shares, and any other Equity Securities required by the Agreement to be bound hereby, shall be bound by and subject to the terms of the Agreement and (b) adopts the Agreement with the same force and effect as if the New Holder were originally a Party thereto.

1.3 Notice. Any notice required or permitted by the Agreement shall be given to New Holder at the address or facsimile number listed below the New Holder’s signature hereto.

[REMAINDER OF PAGE INTENTIONALLY LEFT BLANK]

 

B-1


[NEW HOLDER]

By:    
 

Name:

 

Title:

 

Mailing Address:

 

 

Phone Number:

   
    

Facsimile Number:

   
 

Email Address:

   

 

B-2


ACCEPTED AND AGREED:

 

VENTURE GLOBAL, INC.

By:    
 

Name: [  ]

 

Title: [  ]

 

B-3

Exhibit 10.2

Execution Version

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

SECOND AMENDED AND RESTATED

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

between

VENTURE GLOBAL PLAQUEMINES LNG, LLC

as Owner

and

KZJV LLC

as Contractor

Dated as of January 7, 2022

RELATING TO PHASE 1 OF THE LNG EXPORT AND LIQUEFACTION FACILITY

TO BE LOCATED ON THE WEST BANK OF THE MISSISSIPPI RIVER, NEAR

RIVER MILE MARKER 55, IN PLAQUEMINES PARISH, LOUISIANA


TABLE OF CONTENTS

 

     Page  

1.  DEFINITIONS

     2  

2.  AGREEMENT; EXHIBITS; CONFLICTS

     24  

2.1

  LANGUAGE OF AGREEMENT      24  

2.2

  PRECEDENCE OF AGREEMENT      24  

2.3

  INTERPRETATION      25  

2.4

  NEGOTIATION AND DOCUMENTATION OF THIS AGREEMENT      26  

3.  GENERAL PROVISIONS

     26  

3.1

  WORK TO BE PERFORMED      26  

3.2

  GENERAL OVERSIGHT AND ACCESS      27  

3.3

  JOB SITE CONDITIONS      28  

3.4

  OWNER NOT RESPONSIBLE FOR ACTS OF CONTRACTOR; CONTRACTOR NOT RESPONSIBLE FOR OWNER SCOPE OF WORK      28  

3.5

  EFFECT OF AND TIME FOR OWNER REVIEW OF DOCUMENTS      29  

3.6

  CLAIMS UPON FAILURE OF MATERIAL      29  

3.7

  RESPONSIBILITIES OF OWNER      30  

3.8

  RESPONSIBILITIES OF CONTRACTOR      31  

3.9

  SPARE PARTS      40  

3.10

  PROCUREMENT      40  

4.  COMMENCEMENT OF THE WORK

     41  

4.1

  NOTICE TO PROCEED      41  

4.2

  LIMITED NOTICES TO PROCEED      42  

5.  PERSONNEL AND QUALIFICATIONS

     42  

5.1

  GENERAL      42  

5.2

  KEY PERSONNEL      43  

6.  PRICE AND PAYMENT

     44  

6.1

  TARGET PRICE      44  

6.2

  NOT USED      44  

6.3

  PAYMENT      44  

6.4

  ENCUMBRANCES      46  

6.5

  DEFICIENT REQUESTS FOR PAYMENT      47  

6.6

  OWNER PAYMENT OBLIGATIONS      47  

 

i


6.7

  FINAL PAYMENT      48  

6.8

  OWNER’S RIGHT TO WITHHOLD PAYMENT      48  

6.9

  RELEASE OF LIABILITY      49  

7.  NET LNG SALES PROCEEDS

     49  

7.1

  PRE-COMMERCIAL PRODUCTION      49  

7.2

  NO GUARANTY OF NET LNG SALES PROCEEDS      51  

8.  COST OVERRUN; COST SAVINGS

     50  

8.1

  TOTAL COSTS      50  

8.2

  COST OVERRUN      50  

8.3

  COST SAVINGS      52  

9.  PERFORMANCE SECURITY

     52  

9.1

  TYPES OF PERFORMANCE SECURITY      52  

9.2

  PERFORMANCE AND PAYMENT BONDS      53  

9.3

  CONTRACTOR GUARANTEES      53  

10.  QUALITY CONTROL AND INSPECTION

     54  

10.1

  QUALITY MANAGEMENT PLAN      54  

10.2

  DEFECTS AND DEFICIENCIES      54  

10.3

  INSPECTION RIGHTS      55  

10.4

  THIRD PARTY INSPECTION      56  

10.5

  EFFECT OF WAIVER OF INSPECTION RIGHTS      56  

11.  HEALTH, SAFETY, SECURITY AND ENVIRONMENT

     56  

11.1

  COMPLIANCE      56  

11.2

  HSSE PROGRAM      57  

11.3

  SAFEGUARDS      57  

11.4

  HSSE INCIDENTS      58  

12.  CHANGES IN THE WORK

     58  

12.1

  GENERAL      58  

12.2

  CHANGE ORDER PROCESS      60  

12.3

  DISPUTED CHANGES      61  

12.4

  CHANGES DUE TO UNKNOWN SUBSURFACE CONDITIONS      62  

12.5

  INFORMATION REQUESTS      62  

13.  PROJECT SCHEDULE AND MONTHLY PROGRESS REPORTS

     62  

13.1

  GENERAL      62  

 

ii


13.2

  PROJECT SCHEDULE      63  

13.3

  MONTHLY PROGRESS REPORTS      63  

14.  TRAINING

     63  

15.  TESTING

     64  

15.1

  FACTORY TESTS      64  

15.2

  DEMONSTRATION TESTING      64  

15.3

  PERFORMANCE TESTING      64  

15.4

  CORRECTION OF PERFORMANCE DEFECTS OR DEFICIENCIES      66  

16.  TIME FOR PERFORMANCE AND SCHEDULE

     67  

16.1

  TIME FOR COMPLETION      67  

16.2

  FAILURE TO MITIGATE      68  

16.3

  RECOVERY AND ACCELERATION OF WORK      68  

17.  SUSPENSION OR REJECTION OF THE WORK

     69  

17.1

  GENERAL      69  

17.2

  COMPENSATION TO CONTRACTOR FOR SUSPENSION      70  

17.3

  REJECTION OF WORK      70  

17.4

  CORRECTION OF WORK OR MATERIAL      70  

17.5

  FAILURE TO CORRECT MATERIAL      71  

17.6

  OTHER MATERIAL OR WORK DAMAGED      71  

18.  LNG PRODUCTION SYSTEM COMPLETION

     71  

18.1

  LNG PRODUCTION SYSTEM MECHANICAL COMPLETION      71  

18.2

  LNG PRODUCTION SYSTEM RFSU      72  

18.3

  LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION      73  

19.  FACILITY COMPLETION

     74  

19.1

  FACILITY MECHANICAL COMPLETION      74  

19.2

  FACILITY SUBSTANTIAL COMPLETION      74  

19.3

  READY FOR SHIP LOADING      76  

19.4

  FINAL COMPLETION      76  

19.5

  PUNCH LIST ITEMS      77  

20.  WARRANTY FOR DEFECTS

     78  

20.1

  IN GENERAL      78  

20.2

  SPECIFIC WARRANTIES      78  

20.3

  NOTICE OF DEFECTS OR DEFICIENCIES      79  

20.4

  EXTENSION OF WARRANTY PERIOD      80  

 

iii


20.5

  FAILURE TO REMEDY DEFECTS      80  

20.6

  REMOVAL AND OWNERSHIP OF DEFECTIVE WORK      80  

20.7

  FURTHER TESTS      80  

20.8

  RIGHT OF ACCESS      80  

20.9

  SUBCONTRACTOR AND AGENT FOR CONTRACTOR WARRANTIES      81  

20.10

  NO IMPLIED WARRANTIES      81  

20.11

  REPAIRS AND TESTING BY OWNER      82  

20.12

  SURVIVAL OF WARRANTIES      82  

21.  LIABILITY

     82  

21.1

  TOTAL LIABILITY CAP      82  

21.2

  NO CONSEQUENTIAL DAMAGES      83  

21.3

  JOINT AND SEVERAL LIABILITY      83  

22.  PERFORMANCE TESTS; LIQUIDATED DAMAGES

     83  

22.1

  PERFORMANCE TESTS      83  

22.2

  SCHEDULE DELAY LIQUIDATED DAMAGES FOR FAILURE TO ACHIEVE LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION OR FACILITY SUBSTANTIAL BY AN APPLICABLE DEADLINE      84  

22.3

  LIQUIDATED DAMAGES CAP      87  

22.4

  PAYMENT      88  

22.5

  LIQUIDATED DAMAGES REASONABLE      88  

22.6

  EFFECT ON OTHER PROVISIONS      88  

23.  SUBCONTRACTORS

     88  

23.2

  CONTRACTOR RESPONSIBLE FOR WORK      90  

23.3

  ASSIGNMENT      90  

23.4

  AGENT FOR CONTRACTS WORK      90  

24.  LABOR RELATIONS

     91  

24.1

  GENERAL MANAGEMENT OF EMPLOYEES      91  

24.2

  WAGES AND CONDITIONS      91  

24.3

  VIOLATIONS      91  

24.4

  DISPUTES      91  

24.5

  STATUTORY EMPLOYER      92  

24.6

  LOCAL LABOR      92  

24.7

  COMMUNITY IMPACTS      92  

25.  TITLE AND RISK OF LOSS

     92  

25.1

  TRANSFER OF TITLE      92  

25.2

  RISK OF LOSS      93  

 

iv


25.3

  PROTECTION OF OWNER      93  

26.  INSURANCE

     93  

26.1

  IN GENERAL      93  

26.2

  POLICIES TO BE OBTAINED BY CONTRACTOR      95  

26.3

  POLICIES TO BE OBTAINED BY OWNER      99  

27.  CONFIDENTIAL TREATMENT OF PROPRIETARY INFORMATION; RELIANCE ON INFORMATION

     101  

27.1

  CONFIDENTIAL TREATMENT      101  

27.2

  RELIANCE ON INFORMATION      103  

28.  REPRESENTATIONS AND WARRANTIES

     103  

28.1

  OWNER REPRESENTATIONS AND WARRANTIES      103  

28.2

  CONTRACTOR REPRESENTATIONS AND WARRANTIES      103  

29.  INTELLECTUAL PROPERTY AND LICENSES

     105  

29.1

  OWNERSHIP      105  

29.2

  LICENSES      106  

29.3

  DATA      106  

30.  INDEMNIFICATION

     107  

30.1

  CONTRACTOR INDEMNITY      107  

30.2

  OWNER INDEMNITY      109  

30.3

  ACTIONS BY EMPLOYEES      109  

30.4

  NOTICE AND DEFENSE      109  

30.5

  REMEDIES NOT EXCLUSIVE      110  

30.6

  TAX EFFECT OF INDEMNIFICATION      110  

31.  EVENTS OF DEFAULT; REMEDIES

     110  

31.1

  CONTRACTOR EVENTS OF DEFAULT      110  

31.2

  REMEDIES      113  

31.3

  DAMAGES      113  

31.4

  OWNER REMEDIES      114  

31.5

  OWNER DEFAULT      114  

31.6

  OBLIGATIONS UPON TERMINATION      115  

32.  TERMINATION FOR CONVENIENCE

     116  

32.1

  GENERAL      116  

32.2

  CLAIMS FOR PAYMENT FOLLOWING TERMINATION FOR CONVENIENCE      116  

 

v


33.  FORCE MAJEURE

     117  

33.1

  EXTENSION OF TIME FOR FORCE MAJEURE EVENT      117  

33.2

  CONTRACTOR’S RESPONSIBILITY      117  

33.3

  CONTINUING RESPONSIBILITY OF CONTRACTOR      117  

33.4

  PERFORMANCE NOT EXCUSED      117  

34.  DUTIES AND TAXES

     118  

34.1

  ALLOCATION OF RESPONSIBILITIES      118  

34.2

  LOUISIANA TAX AND INCENTIVES PROVISIONS      118  

35.  BINDING AGREEMENT; ASSIGNMENT

     118  

35.1

  BY OWNER      118  

35.2

  BY CONTRACTOR      119  

36.  DISPUTES

     119  

36.1

  DISPUTE RESOLUTION      119  

36.2

  CONTINUATION OF WORK DURING DISPUTE      121  

36.3

  EXPERT DETERMINATION      121  

37.  INDEPENDENT CONTRACTOR

     122  

37.1

  GENERAL      122  

37.2

  EMPLOYEES      122  

37.3

  RESPONSIBILITY FOR SUBCONTRACTORS, ETC.      122  

38.  NOTICES AND COMMUNICATIONS

     122  

38.1

  REQUIREMENTS      122  

38.2

  EFFECTIVE TIME      123  

38.3

  TECHNICAL COMMUNICATIONS      123  

39.  FINANCING MATTERS

     124  

40.  COMPLIANCE WITH LAWS

     124  

40.1

  ANTI-CORRUPTION      124  

40.2

  RECORDS      125  

40.3

  EXPORT CONTROLS      126  

40.4

  SUBCONTRACTORS; INDEMNIFICATION      126  

41.  MISCELLANEOUS

     127  

41.1

  FURTHER ASSURANCES AND EXPENSES      127  

41.2

  RECORD RETENTION      127  

41.3

  NO WAIVER      127  

 

vi


41.4

  SEVERABILITY      128  

41.5

  BINDING ON SUCCESSORS      128  

41.6

  GOVERNING LAW      128  

41.7

  SET-OFF      128  

41.8

  AMENDMENT      128  

41.9

  HEADINGS FOR CONVENIENCE ONLY      128  

41.10

  NONDISCRIMINATION      129  

41.11

  COUNTERPART EXECUTION      129  

41.12

  THIRD-PARTY BENEFICIARIES      129  

41.13

  SURVIVAL OF OBLIGATIONS      129  

41.14

  ENTIRE AGREEMENT      129  

41.15

  RELATIONSHIP      130  

41.16

  LIMITED RECOURSE      130  

 

vii


Exhibits:      
Exhibit A    Scope of Work; Applicable Codes and Standards
Exhibit B    Compensation   
   Exhibit B-1    Direct Costs and Non-Reimbursable Costs
   Exhibit B-2    Target Price Components
   Exhibit B-3    Cover Costs Examples
   Exhibit B-4    Payment Procedures
Exhibit C    Contractor Rates
Exhibit D    Schedule Milestones
Exhibit E    Project Schedule
Exhibit F    Contract Forms
   Exhibit F-1    Form of Contractor Certificate for Partial Waiver of Liens
   Exhibit F-2    Form of Subcontractor Certificate for Partial Waiver of Liens
   Exhibit F-3    Form of Contractor Certificate for Final Waiver of Liens
   Exhibit F-4    Form of Subcontractor Certificate for Final Waiver of Liens
   Exhibit F-5    Form of Consent and Agreement
   Exhibit F-6    Forms of Contractor Guarantee
   Exhibit F-7    Form of Request for Payment
   Exhibit F-8    Form of Limited Notice to Proceed
   Exhibit F-9A    Form of Performance Bond
   Exhibit F-9B    Form of Payment Bond
   Exhibit F-10    Form of Change Order
   Exhibit F-11    Form of LNG Production System Mechanical Completion Certificate
   Exhibit F-12    Form of LNG Production System RFSU Certificate
   Exhibit F-13    Form of Notice to Proceed
   Exhibit F-14    Form of Title Insurance Indemnity Undertaking
   Exhibit F-15    Form of Payment Status Affidavit (Contractor)
   Exhibit F-16    Form of Subcontractor’s Payment Status Affidavit
Exhibit G    Training Requirements
Exhibit H    Schedule of Major Vendors
Exhibit I    Progress Reporting and Progress Meetings
Exhibit J    Document Control and Information Management
Exhibit K    List of Contractor’s Key Personnel
Exhibit L    Permits, Licenses and Government Approvals
Exhibit M    Relied Upon Information
Exhibit N    Owner Supplied Information
Exhibit O    Schedule of Major Subcontractors
Exhibit P    Mechanical Completion, Commissioning, Start-up and Substantial Completion
Exhibit Q    Owner Personnel
Exhibit R    Demonstration Tests and Performance Tests
Exhibit S    LNG Production System Handover Packages
Exhibit T    Requirements for Simultaneous Operation
Exhibit U    Health, Safety, Security and Environment Requirements
Exhibit V    First Fills and Catalysts

 

1


Exhibit W    Open Cost Items
Exhibit X    Cost Overrun and Cost Saving Adjustments
Exhibit Y    Coordination Procedure
Exhibit Z    Contractor’s Proposal

 

2


 

THIS SECOND AMENDED AND RESTATED ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Agreement”) is made and entered into as of January 7, 2022 (the “Second Restatement Date”) by and between VENTURE GLOBAL PLAQUEMINES LNG, LLC (“Owner”), a limited liability company duly organized and validly existing under the laws of the State of Delaware domiciled in and with its principal place of business located at 1001 19th Street North, Suite 1500, Arlington, VA 22209, and KZJV LLC, a limited liability company duly organized and validly existing under the laws of the State of Texas with its principal place of business at Corporation Trust Center, 1999 Bryan Street, Suite 900, Dallas, Texas 75201 (the “Contractor”).

W I T N E S E T H

WHEREAS, Owner is developing and intends to own and operate natural gas liquefaction facilities, including two phases, an export terminal and LNG storage facilities located on the west bank of the Mississippi River, near river mile marker 55, in Plaquemines Parish, Louisiana, all as more fully described herein and the Exhibits hereto;

WHEREAS, Owner desires to engage Contractor to perform certain design, engineering, procurement, and construction-related services in respect of the first phase, with a nameplate capacity of thirteen decimal three (13.3) million metric tonnes per annum of LNG, all as more fully described herein and in the Exhibits hereto;

WHEREAS, Contractor has (a) been provided and reviewed the conceptual drawings, the Owner Contracts and the other information relating to the Facility (as hereinafter defined) and all other documents relating to the Facility which Contractor and Owner have deemed necessary in connection with this Agreement, (b) inspected the Job Site (as hereinafter defined) and (c) performed or reviewed such other investigations, studies and analyses, which Contractor has determined to be necessary or prudent, in connection with the performance of the Work (as hereinafter defined);

WHEREAS, Contractor has represented that it is experienced and qualified in providing technical assistance, licensing, engineering, procurement, supply, construction management, construction, Pre-Commissioning (as hereinafter defined), Commissioning (as hereinafter defined) and testing services, and that it possesses the requisite expertise and resources to complete the Work to be performed by it;

WHEREAS, Contractor desires to complete the Work for Owner;

WHEREAS, Contractor (as successor in interest by assignment from Kellogg Brown & Root LLC) and Owner were parties to that certain Engineering, Procurement and Construction Agreement dated as of the Effective Date (the “Original Agreement”);

WHEREAS, Contractor and Owner entered into that certain Amended and Restated Engineering, Procurement and Engineering Agreement (the “First Amended and Restated Agreement ”) dated as of April 21, 2021 (the “First Restatement Date”), which replaced and superseded the Original Agreement in its entirety; and

WHEREAS, Contractor and Owner desire to amend and restate the First Amended and Restated Agreement in its entirety as set forth in this Agreement.


NOW, THEREFORE, in consideration of the sums to be paid to Contractor by Owner and of the covenants and agreements set forth herein, and for other good and valuable consideration, the receipt and adequacy of which is hereby acknowledged, the Parties hereto, intending to be legally bound, hereby agree as follows:

 

1.

DEFINITIONS.

For all purposes of this Agreement, except as otherwise expressly provided or unless the context otherwise requires, the following terms when capitalized herein (including the Exhibits) shall have the following meanings:

Abandonment of the Project” means Contractor’s refusal to perform substantially all home office activities and field construction operations in a manner that manifests the intent by Contractor of not completing the Work under this Agreement.

Adjustment Dispute” has the meaning set forth in Section 36.3.

Affiliate” means, in relation to any Person, any other Person: (a) which directly or indirectly controls, or is controlled by, or is under common control with, such Person; or (b) which directly or indirectly beneficially owns or holds fifty percent (50%) or more of any class of voting stock or other equity interests of such Person, or (c) which has fifty percent (50%) or more of any class of voting stock or other equity interests that is directly or indirectly beneficially owned or held by such Person or (d) who either holds a general partnership interest in such Person or such Person holds a general partnership interest in the other Person. For purposes of this definition, the word “controls” means possession, directly or indirectly of the power to direct or cause the direction of the management or policies of a Person, whether through the ownership of voting securities or otherwise. For the avoidance of doubt, each Contractor Guarantor and each JV Member shall be deemed to be an Affiliate of Contractor under this Agreement.

Agent For Contractor” means any party to an Agent For Contract (other than Owner).

Agent For Contracts” means:

(a) the Site Wide Final Grading Agreement between Owner and Remedial Construction Services, L.P., dated as of December 9, 2021;

(b) the Soil Improvement A2/A3 Agreement between Owner and ENTACT Environmental Services, Inc. dated as of November 11, 2021;

(c) the Site Wide Final Grading Agreement between Owner and WT Byler Co., Inc., dated as of December 10, 2021;

(d) the LNG Tank Soil Replacement Agreement between Owner and Beard Construction Group dated as of October 25, 2021;

(e) the module fabrication and construction agreement to be entered into between Owner and the relevant Agent For Contractor; and

 

2


(f) the module transportation agreement to be entered into between Owner and the relevant Agent For Contractor.

Agent For Contracts Costs” means the amounts payable by Owner pursuant to and in accordance with the Agent For Contracts, excluding any amounts payable thereunder solely as a result of the Gross Negligence or Willful Misconduct of Senior Supervisory Personnel.

Agent For Contracts Work” means scope of work and other obligations set forth in the Agent For Contracts.

Agreement” has the meaning set forth in the introductory paragraph hereof, and shall be deemed to include all Exhibits to this Agreement, as each of the foregoing may be amended, modified and supplemented from time to time pursuant to the terms hereof.

Anti-Corruption Laws” has the meaning set forth in Section 40.1.2.

Anticipated NTP Date” means [***].

Applicable Codes and Standards” means those certain codes, requirements and standards applicable to the Facility, the Job Site, the Work, Contractor and/or any Subcontractors set forth in Exhibit A or in any applicable Law. In the event of an inconsistency or conflict between any of the Applicable Codes and Standards, the more stringent standard as contemplated therein shall govern Contractor’s performance under this Agreement.

Applicable Deadline” means an LNG Production System Substantial Completion Deadline, the Facility Substantial Completion Deadline or the Final Completion Deadline, as applicable.

BH” means Baker Hughes Energy Services LLC, a Delaware limited liability company.

BH Testing Delay” has the meaning set forth within the definition of Owner Caused

Delay.

Block” means a grouping of two (2) Liquefaction Trains in a Liquefaction Train System.

BSCFD” means Billion Standard Cubic Foot per Day.

Btu ” or “British Thermal Unit” means the amount of heat required to raise the temperature of one avoirdupois pound of pure water from fifty-nine degrees (59°) Fahrenheit to sixty degrees (60°) Fahrenheit at a pressure of fourteen point six nine six (14.696) pounds per square inch absolute (psia).

Business Day” means any Day other than a Saturday, Sunday or a legal holiday in the State of New York (solely for the purpose of a payment obligation) or the State of Louisiana (with respect to all other obligations).

 

3


Carrollton Gage” means the gauge for measuring river level height of the Mississippi River located at Mississippi River mile 102.8 near New Orleans, Louisiana and commonly known as the “Carrollton gauge” or “Carrollton gage.”

Carrollton Gage Delay” means a Government Authority, including the United States Army Corps of Engineers or any applicable levee district, issues a navigation notice, denies, revokes, suspends or modifies a levee permit or a waiver application in respect to a levee permit, or formally takes any other action that has the effect of preventing or adversely impacting navigation, transport, loading, or unloading activity along an applicable stretch or stretches of the Mississippi River or construction activity within a prescribed distance from the Mississippi River levee or berm toe (e.g., subsurface work within 1,500 feet from the Mississippi River levee centerline), in each case due to the river stage exceeding eleven (+11.0) feet National Geodetic Vertical Datum (NGVD) at the Carrollton Gage, which directly and adversely impacts Contractor’s performance of Work at or near the Job Site.

Change in Law” means (a) the enactment or issuance of any new Law or Permit applicable to the Facility, the Job Site and/or the Parties, (b) the amendment, alteration, modification or repeal of any existing Law or Permit applicable to the Facility (including any change to Facility noise or emissions limitations), the Job Site and/or the Parties, (c) any authoritative interpretation of any existing Law or Permit applicable to the Facility, the Job Site and/or the Parties, expressed in writing and issued by a Government Authority that is contrary to the existing official interpretation thereof, or (d) or any change in the Applicable Codes and Standards, which in the case of any of (a), (b), (c) or (d) above is enacted or adopted and is imposed and/or comes into effect after the Effective Date, and that must be complied with in order for the Facility to be constructed or operated lawfully; provided, however, that any change in any Law relating to income, capital, net worth or income withholding taxes shall not constitute a Change in Law for purposes hereof.

Change Order” means a document issued pursuant to Article 12 which authorizes, as applicable, a change in or to (a) the Work or the requirements set forth in Exhibit A, (b) the Target Price, (c) the Project Schedule, (d) the Critical Path, (e) an Applicable Deadline, (f) the (g) the Demonstration Tests; (h) Performance Tests (or protocol therefor) or (i) any right, liability or obligation of a Party or any other provision hereof, and is in the form attached hereto as Exhibit F-10.

Commissioning” means the commissioning activities performed by Contractor with respect to an LNG Production System after LNG Production System Mechanical Completion and Pre-Commissioning for such LNG Production System has occurred, as set forth in Exhibit P and Owner has accepted a Ready for Commissioning Certificate for such LNG Production System in accordance with Exhibit P. Commissioning includes all of the activities that are required to be completed in order to put the equipment and facilities into operation, to dynamically verify functionality of equipment and to ensure that systems, or facilities forming part of a system, are in accordance with specified requirements to bring that system into operation, including specialist flushing and cleaning, chemical and hydraulic cleaning, drying, oxygen freeing nitrogen and helium testing.

Confidential Information” has the meaning set forth in Section 27.1.

 

4


Consent and Agreement” has the meaning set forth in Article 39.

Contractor” has the meaning set forth in the introductory paragraph hereof, and includes legal successors and permitted assigns as may be accepted by Owner, in writing, pursuant to the terms of this Agreement.

Contractor Confidential Information” has the meaning set forth in Section 27.1.2.

Contractor Guarantee” means each of (i) the Guaranty dated as of April 21, 2021 made by KBR, Inc. in favor of Owner and (ii) the Guaranty dated as of April 21, 2021 made by Zachry Holdings, Inc. in favor of Owner, and “Contractor Guarantees” means both of them, collectively.

Contractor Guarantor” means each of (i) KBR, Inc., a Delaware corporation and (ii) Zachry Holdings, Inc., a Delaware corporation, and “Contractor Guarantors” means both of them, collectively.

Contractor Indemnitee” means Contractor, the Contractor’s Representative, and all Affiliates, officers, directors, employees and agents thereof.

Contractor Intellectual Property” means all Intellectual Property that is (a) (i) owned by or licensed to Contractor as of the First Restatement Date or by Contractor’s Affiliates as of the Effective Date or (ii) acquired during the term of this Agreement other than in connection with the Work, (b) disclosed by Contractor hereunder, and (c) necessary for, or used or held for use by Contractor and/or any Subcontractor in connection with the performance, completion, design, construction, installation, operation, maintenance, repair, replacement, modification, alteration or reconstruction of the Work.

Contractor’s G&A” means, in respect of each month that Contractor is eligible for reimbursement of Direct Costs or is managing Agent For Contractor Work, Contractor’s general and administrative expenses for such month, which shall be a fixed percentage during the term hereof and equal at all times to [***] of the sum of the amount of Direct Costs that are reimbursable to Contractor and the Agent For Contracts Costs in respect of such month all as specifically defined in Exhibit B.

Contractor’s Margin” means, in respect of each month that Contractor is eligible for reimbursement of Direct Costs or is managing Agent For Contractor Work, Contractor’s profit margin for such month in respect of such Direct Costs, which shall be equal at all times to the sum of the amount of Direct Costs that are reimbursable to Contractor and the Agent For Contracts Costs in respect of such month multiplied by the Margin Percentage all as specifically defined in Exhibit B.

Contractor’s Representative” means Contractor’s employee designated by Contractor pursuant to Section 3.8.32.

Corrective Work” has the meaning set forth in Section 20.1.3.

Cost Overrun” means an amount equal to the amount by which the Total Costs exceed the Target Price.

 

5


Cost Savings” means an amount equal to the amount by which the Target Price exceeds the Total Costs.

Cover Costs” has the meaning set forth in Section 31.3.

Critical Path” means the longest duration series of interdependent engineering, procurement, construction, Pre-Commissioning, Commissioning and testing activities described in or prepared in accordance with Exhibit E relating to the Work logically connected end to end using critical path method precedence networking techniques agreed to in writing by Owner and Contractor prior to the Notice to Proceed Date, which determines the total duration of the Project Schedule from the commencement of the Work to Facility Substantial Completion or Applicable Deadline, if different.

Customer Commercial Operation Date” means the date on which Owner is obligated under its long-term LNG sales and purchase agreements to make available LNG for sale under such agreements, as notified to Contractor by Owner.

Day” or “day” means a period of twenty-four (24) consecutive hours from 12:00 midnight (Central time), and shall include Saturdays, Sundays and all holidays except that in the event a time period set forth herein expires on a Day that is not a Business Day, such period shall be deemed to expire on the next Business Day thereafter.

Defects” or “Deficiencies” means any components, tools, Materials, installation (including the installation and integration of Owner Furnished Equipment and Materials by Contractor or its Subcontractors), construction, workmanship or Work (including any Corrective Work) that, in Owner’s reasonable judgment, (a) do not conform to the terms of this Agreement or any Warranty or (b) are not of uniform good quality, or designs which fail to conform to the Applicable Codes and Standards, Owner Standards and all other requirements of this Agreement, including Exhibit A (to the extent designed by Contractor or its Subcontractors), application, manufacture or workmanship, or that contain improper or inferior workmanship. Defects and Deficiencies shall not be deemed to include breakdown or damage caused by (i) Owner’s, its Affiliates’ or Owner Contractors’ negligence or Willful Misconduct, (ii) Owner’s failure to supply Owner Furnished Equipment and Materials, or failure of the Owner Furnished Equipment and Materials to perform in accordance with the requirements of this Agreement and of the applicable Owner Contract pursuant to which such Owner Furnished Equipment and Materials were purchased by Owner, or Owner’s failure to perform the Owner Scope of Work, (iii) Owner’s failure to operate or maintain an LNG Production System or the Facility in accordance with operations and maintenance manuals provided to Owner by Contractor or an Owner Contractor, (iv) any repair, alteration or modification by third parties (unless such third party was an Agent For Contractor or approved by Contractor or was retained by Owner to perform such repair, alteration or modification in accordance with this Agreement where Contractor failed to initiate correction of Work), (v) normal wear and tear, or (vi) any effects of the elements on, or use outside of the design parameters of, an LNG Production System or the Facility, including distortion, corrosion, abrasion, material changes to the operating conditions (such as temperature, pressure, or changes in material product composition).

 

6


Deliverables ” means all Drawings and Specifications, records, manuals, programs, registers and written procedures required pursuant to the terms of this Agreement (including Exhibit Y) to operate and maintain the Work for the Facility and training of the Facility’s operation and maintenance personnel via classroom and hands-on sessions pursuant to the terms hereof, excluding Deliverables provided under the Owner Contracts.

Demonstration Tests” has the meaning set forth in Exhibit R.

Direct Costs” means the actual, verifiable and documented costs incurred by Contractor with respect to the performance of the Reimbursable Work based upon the labor rates, unit rates and actual out-of-pocket costs and expenses, in each case, as described in more particular detail in Exhibit B-1 and Exhibit C and that are incurred by Contractor in accordance with this Agreement, excluding any Non-Reimbursable Costs.

Dispute” has the meaning set forth in Section 36.1.1.

Dollar” and “$” means the lawful currency of the United States of America.

Drawings and Specifications” means all specifications, calculations, designs, plans, drawings, engineering and analyses, operation and maintenance manuals, original equipment manufacturer manuals, material safety data sheets, operating instructions, system checklists, start-up procedures, Pre-Commissioning, Commissioning procedures and checklists, System Turnover Packages required to be delivered by Contractor hereunder or required to be delivered by an Agent For Contractor under an Agent For Contract, alignment checklists and all other documents of the Work, including the structure and foundation thereof, either (a) described in or attached to this Agreement or any Agent For Contract or (b) prepared or modified by Contractor or any Subcontractor with respect to the Work or any Agent For Contractor with respect to any Agent For Contracts Work, excluding Drawings and Specifications provided under the Owner Contracts.

EAR” has the meaning set forth in Section 40.3.1.

Effective Date” means November 9, 2020.

Environmental Laws” means any Law relating to the regulation or protection of human health, safety, natural resources or the environment or to the remediation, manufacture, generation, production, installation, use, sale, storage, treatment, transportation, Release, threatened Release, exposure to, or disposal of Hazardous Substances.

Estimated Monthly Amount” has the meaning set forth in Section 6.3.1.

Expert” has the meaning set forth in Section 36.3.

Export Controls” has the meaning set forth in Section 40.3.1.

 

7


Facility” means (a) the first phase of Owner’s Plaquemines LNG export terminal and liquefaction project, with a nameplate capacity of thirteen decimal three (13.3) MTPA of LNG, to be located at the Job Site and more specifically described as the fully operational, complete project (including Materials and Owner Furnished Equipment and Materials incorporated therein) to be

designed, engineered, procured, constructed, pre-commissioned, tested, delivered and warranted under this Agreement in order to successfully pass the Performance Tests and meet or exceed the requirements set forth in Exhibit A, and consisting of the Liquefaction Train System, the LNG Storage Tanks, the Pre-Treatment System and the marine terminal and including all Materials necessary to safely and efficiently transport and process Feed Gas through each LNG Production System, load and store LNG in the LNG Storage Tanks, transport LNG to, and load LNG on, an LNG Tanker, and otherwise process, transport, store load and unload LNG and Feed Gas, all as more particularly described in Exhibit A together with the supporting improvements and interconnections related thereto, as specifically addressed in the Exhibits hereto, and (b) the Power Plant.

Facility Mechanical Completion” means the acceptance by Owner of the Facility after satisfaction of the applicable conditions set forth in Exhibit P and Section 19.1.

Facility Mechanical Completion Date” means the date on which Facility Mechanical Completion occurs in accordance with Section 19.1.

Facility Performance Tests” has the meaning set forth in Section 15.3.4.

Facility Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.5 as liquidated damages for the delay in the achievement of Facility Substantial Completion.

Facility Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(e).

Facility Substantial Completion” means the completion of the Facility in accordance with and to the extent set forth in Section 19.2.

Facility Substantial Completion Date” means the date on which Facility Substantial Completion occurs in accordance with Section 19.2.

Facility Substantial Completion Deadline” means the date identified on Exhibit D.

Feed Gas” means natural gas, in gaseous form, which consists of gas transported by natural gas pipelines in the United States of America.

Feed Gas Interconnection” means the installation of the Materials to the Pipeline Tie Point(s) and all other activities necessary to effect interconnection of the Facility with the civil, mechanical, electrical and control systems of the Gator Express Pipeline.

Field Services Agreement ” means the Field Services Agreement to be entered into by Owner and BH (or BH’s Affiliate).

Final Completion” means the completion of the Facility in accordance with and to the extent set forth in Section 19.4.

 

8


Final Completion Date” means the date on which Final Completion occurs in accordance with Section 19.4.

Final Completion Deadline” means the date that is [***] days after the Facility Substantial Completion Date.

Final Request for Payment” has the meaning set forth in Section 6.7.

Financial Closing Date” means the closing date for the Financing by the Lenders, at which time all conditions precedent to the drawing of funds thereunder have been satisfied or waived and the initial funds contemplated by the Financing are disbursed to Owner.

Financing” has the meaning set forth in Article 39.

Financing Deliverables” has the meaning set forth in Article 39.

First Amended and Restated Agreement” has the meaning set forth in the recitals.

First Restatement Date” has the meaning set forth in the recitals.

Force Majeure Event” means any act, event or condition that (a) arises after the Second Restatement Date and (b) has an impact which will actually, demonstrably and adversely affect a Party’s ability to perform its obligations in accordance with this Agreement (excluding obligations to pay money due) or will actually, demonstrably and adversely affect the Critical Path, in each case, to the extent that such act, event or condition (i) is beyond the reasonable control of the Party relying thereon, (ii) is not the result of any unreasonable acts, omissions or delays of the Party relying thereon (or any Third Party over whom such Party has control, including any Subcontractor) (iii) is not an act, event or condition, the risks or consequences of which such Party has expressly agreed to assume hereunder, or (iv) that could not be avoided by the exercise of reasonable precautions, efforts and measures (including planning, scheduling and rescheduling), whether before, after or during such act, event or condition. “Force Majeure Event” includes the following (if the conditions and requirements described above are satisfied): hurricanes, named tropical storms, floods, storm surge, tsunamis, lightning strike, volcanic eruptions, tornados, or other unusually severe conditions; government decreed official state of emergency or other governmental action of a Government Authority; fire, earthquakes and explosions; epidemics (including the epidemic known as COVID-19); contamination by nuclear, chemical, or biological cause; acts of war (whether declared or undeclared); civil unrest at or in the immediate proximity of the Job Site; accidents of navigation; sabotage or terrorism; and strikes, work stoppages or other labor actions that are not directed solely at Contractor or any Subcontractor; and Change in Law. Notwithstanding the foregoing, “Force Majeure Event” does not include (i) strikes, work stoppages (or deteriorations), slowdowns or other labor actions directed solely at Contractor or any Subcontractor or any Agent For Contractor solely involving the employees of Contractor or any Subcontractor or any Agent For Contractor, (ii) weather conditions (other than those expressly defined as Force Majeure Events above) which could reasonably be anticipated by experienced professional design and construction contractors familiar with building comparable facilities on the Gulf Coast of the United States of America, (iii) any Job Site Condition or event arising therefrom, (iv) the occurrence of any manpower, craft labor or Materials shortages (unless otherwise caused by a Force Majeure Event), (v) any failure by Contractor or any Agent For

 

9


Contractor to obtain and/or maintain any Permit it is required to obtain and/or maintain hereunder, (vi) any delay, default or failure (direct or indirect) in obtaining Materials or of any Subcontractor or any other delay, default or failure (financial or otherwise) of a Subcontractor or Agent For Contractor (unless otherwise caused by a Force Majeure Event), or (vii) changes in market conditions.

Gas Turbine” means that component of the Power Plant which generates power to drive a generator by exhausting gases produced by the combustion of fuel and compressed air through a Brayton cycle turbine.

Gator Express Pipeline” means, collectively, the natural gas pipelines interconnected with the Facility, as more specifically described in Exhibit A.

Geotechnical Reports” means those reports furnished by Owner to Contractor prior to the execution of this Agreement, as further described in Exhibit M.

Government Authority” means any agency, authority, department, court, tribunal, ministry, legislative body, commission, instrumentality, public person, statutory or legal entity, person (whether autonomous or not), or other subdivisions of any of the above having a regulatory interest in or jurisdiction over any Party, the Job Site, the performance of the Work, or the Facility (or the construction or operation thereof).

Government Official” has the meaning set forth in Section 40.1.3.

Gross Negligence ” means any act or failure to act by a Person which (i) seriously and substantially deviates from a diligent course of action, and (ii) was in reckless disregard of or with wanton indifference to, harmful consequences such Person knew, or should have known, such act or failure would have had.

Hazardous Substances” means any element, compound, mixture, solution, particle or substance:

(a) which is or may become dangerous, harmful or potentially dangerous or harmful to the health and welfare of life, natural resources or the environment, such as, but not limited to, explosives, petroleum products, radioactive, corrosive, flammable, infectious, carcinogenic, or mutagenic materials, hazardous wastes, toxic substances and related materials, and including any substance or material included within the definitions of “hazardous substances,” “hazardous wastes,” “solid wastes,” “hazardous materials,” “chemical substances,” “hazardous pollutants” or “toxic pollutants” in any Law, including any Law relating to the protection of human health, natural resources or the environment;

(b) the presence or Release of which requires investigation or remediation under any applicable Law;

(c) which is listed, defined, regulated or forms the basis for liability under any applicable Law relating to the protection of human health, natural resources or the environment; or

 

10


(d) the presence of which on the Job Site causes or threatens to cause a nuisance upon the Job Site or to the adjacent properties or poses or threatens to pose a hazard to the health or safety of Persons on or about the Job Site or on or about the adjacent properties.

HSSE” has the meaning set forth in Section 11.2.2.

HSSE Program” has the meaning set forth in Section 11.2.1.

ICC” means the International Chamber of Commerce.

Indemnified Liens” has the meaning set forth in Section 6.4.1.

Independent Engineer” means the engineering firm designated by the Lenders to monitor the progress of the Work and conformity of the Work with Owner Standards and the requirements and specifications contained herein.

Initial Request for Payment” means the first Request for Payment that is issued simultaneously with the Notice to Proceed.

Intellectual Property” means all United States and foreign intellectual property, including all (a) inventions (whether or not patentable or reduced to practice), improvements, patents and industrial designs (including utility models, designs, and industrial property) and patent and industrial design applications, and inventions and patent disclosures, together with all renewals, reissues, reexaminations, provisionals, divisionals, revisions, continuations, continuations-in-part, and extensions thereof; (b) works of authorship (whether or not copyrightable), registered and unregistered copyrights, mask works, database rights, and moral rights, together with all applications therefor and renewals thereof; and (c) trade secrets, confidential or proprietary information (including unpublished patent applications, technical data, customer and suppliers lists, pricing and cost information, and business and marketing plans and proposals), technology, know-how, processes, techniques, protocols, specifications, data, compositions, industrial models, architectures, layouts, designs, drawings, plans, ideas, research and development, formulae, algorithms, models, and methodologies.

Intellectual Property Claim” means any claim, demand, suit or legal action to the extent arising out of or based on any actual or alleged unauthorized disclosure, use or misappropriation of any Intellectual Property, or any actual or alleged infringement or other violation of any right in, to or under, any Intellectual Property of any other Person that: (a) concerns any Materials, Deliverables, Inventions or other services or information provided by Contractor, any of its Affiliates, or any Subcontractor under this Agreement or by any Agent For Contractor under any Agent For Contract; (b) is based upon or arises out of the performance of the Work by Contractor, any of its Affiliates, or any Subcontractor or Agent For Contractor, including the use of any tools or other implements of construction by Contractor, any of its Affiliates, or any Subcontractor or any Agent For Contractor; (c) is based upon or arises out of the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem or component thereof) by Contractor or any of its respective Affiliates or Subcontractors under this Agreement or by any Agent For Contractor under any Agent For Contract or their use of any Contractor Intellectual Property in connection therewith; or (d) is based upon or arises out of Owner’s exercise of its rights pursuant to and in accordance with Article 29.

 

11


Inventions” has the meaning set forth in Section 29.1.

Job Site” means the portion of Owner’s real property interests on which the Facility is to be located, plus the laydown areas, rights-of-way, easements and other property rights affixed, connected or associated therewith and such additional areas as may, from time to time, be designated in writing by Owner for Contractor’s use hereunder, as more fully described in Exhibit A.

Job Site Conditions” has the meaning set forth in Section 3.3.

JV Agreement” means that certain Limited Liability Company Agreement for KZJV LLC, entered into between the JV Members on March 16, 2021.

JV Member” means each of Kellogg Brown & Root LLC, a Delaware limited liability company, and Zachry Industrial, Inc., a Texas corporation, and “JV Members” means both of them, collectively.

Key Personnel” means the employees of Contractor named in Exhibit K.

Late Payment Rate” means the lesser of (a) t wo percent (2%) above the per annum Prime Rate reported daily in The Wall Street Journal, or (b) the maximum rate permitted by Law.

Law” means (a) any applicable statute, law, common law, rule, regulation, code, ordinance, judgment, decree, writ, order or the like of any Government Authority and the official interpretations thereof or (b) any official requirements or conditions on or with respect to the issuance, maintenance or renewal of any applicable Permit issued by any Government Authority including laws related to Taxes, import or export charges (including any tariffs, levies and duties).

Lenders” means (a) any Person that does or proposes to provide Financing in respect of the Facility and/or the general business and operations of Owner or its Affiliates (including any refinancing thereof), including any export credit agency, funding agency, bondholder, insurance agency, underwriter, investor, commercial lender or similar institution, together with any agent or trustee for such Person and (b) any provider of any hedging arrangement entered into in connection with the arrangements described in clause (a) above, including an interest rate swap transaction or a forward interest rate swap transaction, in each case, together with any agent or trustee for such provider.

Limited Notice to Proceed” has the meaning set forth in Section 4.2.1.

Liquefaction Train” means the Mixed Refrigerant compression package, including the cold box, surge vessel and other equipment producing approximately [***] MTPA of LNG at design outlet pressure and ambient design conditions of [***] degrees Fahrenheit and [***] relative humidity, at sea level, as further described in Exhibit A.

 

12


Liquefaction Train System” means the Mixed Refrigerant compression package, including the cold box, surge vessel and other equipment in a configuration of twenty-four (24) Liquefaction Trains capable of producing an aggregate of approximately [***] MTPA of LNG at design conditions, as further described in Exhibit A and Exhibit R.

LNG” means liquefied natural gas meeting the requirements described in Exhibit A.

LNG Production System” means LPS1, LPS2, LPS3 or LPS4, as applicable.

LNG Production System Handover Package ” means, with respect to each of LPS1, LPS2, LPS3 or LPS4, the equipment, Materials and Owner Furnished Equipment Materials described in Exhibit S.

LNG Production System Mechanical Completion” means the acceptance by Owner of an LNG Production System after satisfaction of the applicable conditions set forth in Section 18.1 and Exhibit P.

LNG Production System Mechanical Completion Certificate” means the certificate provided by Contractor in the form of Exhibit F-11 certifying the satisfaction of each of the requirements required to achieve LNG Production System Mechanical Completion in Section 18.1.

LNG Production System Mechanical Completion Date ” means, with respect to an LNG Production System, the date on which LNG Production System Mechanical Completion of such LNG Production System occurs in accordance with Section 18.1.

LNG Production System RFSU” means, with respect to an LNG Production System, all of the following conditions are satisfied: (a) Contractor has completed all applicable Work in accordance with this Agreement, including Exhibit P, to ensure that such LNG Production System is ready to receive and utilize Feed Gas, (b) Contractor has achieved LNG Production System Mechanical Completion, and (c) Contractor has delivered to Owner an LNG Production System RFSU Certificate, as required in Section 18.2.

LNG Production System RFSU Certificate” means the certificate provided by Contractor in the form of Exhibit F-12 in advance of the introduction of Feed Gas for Commissioning.

LNG Production System Substantial Completion” means the completion of an LNG Production System in accordance with and to the extent set forth in Section 18.3.

LNG Production System Substantial Completion Date” means, with respect to an LNG Production System, the date on which LNG Production System Substantial Completion of such LNG Production System occurs in accordance with Section 18.3.

LNG Production System Substantial Completion Deadline” means the LPS1 Substantial Completion Deadline, the LPS2 Substantial Completion Deadline, the LPS3 Substantial Completion Deadline or the LPS4 Substantial Completion Deadline, as applicable.

LNG Storage Tank” means one (1) of the two (2) cryogenic LNG storage tanks designed and field erected in accordance with this Agreement, as more particularly described in Exhibit A.

 

13


LNG Storage Tank Cooldown” has the meaning set forth in Section 18.2.2.

LNG Tanker” means an ocean-going vessel suitable for the transportation of LNG which conforms to the specifications set forth in Exhibit A.

LNTP No. 1 (ITP)” has the meaning set forth in Section 4.2.2.

LNTP No. 2” has the meaning set forth in Section 4.2.2.

Loading Rate Test” has the meaning set forth in Exhibit R.

Losses” means any and all losses, liabilities, damages, costs, charges, expenses, fines, interest, awards and penalties, which are the result of or arise from any actions, suits, claims, demands, causes of action, litigation, lawsuits, administrative proceedings or administrative investigations.

LPS1” means the systems and sub-systems comprising a portion of the Facility and including the first [***] Blocks that are collectively identified as such in Exhibit A.

LPS1 Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.1 as liquidated damages for the delay in the achievement of LNG Production System Substantial Completion of LPS1.

LPS1 Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(a).

LPS1 Substantial Completion Date” means the date on which LNG Production System Substantial Completion is achieved for LPS1.

LPS1 Substantial Completion Deadline” means the date so identified on Exhibit D.

LPS2” means the systems and sub-systems comprising a portion of the Facility and including [***] Blocks that are collectively identified as such in Exhibit A.

LPS2 Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.2 as liquidated damages for the delay in the achievement of LNG Production System Substantial Completion of LPS2.

LPS2 Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(b).

LPS2 Substantial Completion Date” means the date on which LNG Production System Substantial Completion is achieved for LPS2.

LPS2 Substantial Completion Deadline” means the date so identified on Exhibit D.

LPS3” means the systems and sub-systems comprising a portion of the Facility and including [***] Blocks that are collectively identified as such in Exhibit A.

 

14


LPS3 Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.3 as liquidated damages for the delay in the achievement of LNG Production System Substantial Completion of LPS3.

LPS3 Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(c).

“LPS3 Substantial Completion Date” means the date on which LNG Production System Substantial Completion is achieved for LPS3.

LPS3 Substantial Completion Deadline” means the date so identified on Exhibit D.

LPS4” means the systems and sub-systems comprising a portion of the Facility and including the final [***] Blocks that are collectively identified as such in Exhibit A.

LPS4 Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.4 as liquidated damages for the delay in the achievement of LNG Production System Substantial Completion of LPS4.

LPS4 Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(d).

“LPS4 Substantial Completion Date” means the date on which LNG Production System Substantial Completion is achieved for LPS4.

LPS4 Substantial Completion Deadline” means the date so identified on Exhibit D.

LTS PO” means that certain Purchase Order Contract for the Sale of the Liquefaction Train System, dated as of February 26, 2021, between Owner and BH.

Major Subcontract” means (a) any Subcontract providing services or Materials for the Work having an aggregate value in excess of [***], (b) multiple Subcontracts with the same Subcontractor (including any Subcontractor that is an Affiliate of Contractor) providing services or Materials for the Work having an aggregate value in excess of [***].

Major Subcontractor” means each Subcontractor that is party to a Major Subcontract.

Make Good Commencement Date” has the meaning set forth in Section 15.3.4.

Margin Milestone” means a milestone identified as a Margin Milestone in Exhibit D.

Margin Percentage” means, initially, [***], as such percentage may be adjusted pursuant to this Agreement.

Material Change” means any proposed Change Order or other amendment, supplement or modification to this Agreement which, (a) delays, extends or changes an Applicable Deadline, (b) modifies the requirements for successfully passing any Demonstration Tests or Performance

 

15


Tests or the manner in which any Demonstration Tests, or Performance Tests are performed or the results thereof are measured, (c) diminishes the scope or duration of any Contractor warranty, (d) alters the amount, timing or manner of payment of any Contractor liquidated damages, (e) causes the Work (or any portion thereof) to materially deviate from the requirements set forth in Exhibit A, (f) increases the Target Price by more than [***] for an individual change or, when aggregated with all other changes previously effected, causes the Target Price to increase by an amount that is more than an [***] or (g) otherwise materially diminishes, lessens or waives any liability or obligation of Contractor under this Agreement or any right or benefit of Owner hereunder. The term “Material Change” is a term distinct and separate from references herein to “material adverse change,” and shall in no way be construed or applied to define the word “material” or “materially” when used herein.

Materials” means those equipment, materials, supplies, apparatus, machinery, parts, tools (including any special tools), components, instruments, appliances, systems, construction and testing-related spare parts and appurtenances thereto (a) required for prudent design, engineering, procurement, construction, installation, Pre-Commissioning, Commissioning, testing, delivery and operation, maintenance and repair of the Work and for the installation, Pre-Commissioning at the Job Site, Commissioning, testing, and operation of the Facility in accordance with Owner Standards and supplied under the terms of this Agreement, (b) described in or required as part of the Work by Exhibit A, excluding, in each case, the Owner Furnished Equipment and Materials.

Mixed Refrigerant ” means a mixture of gases or liquids, including ethylene, propane, i-pentane, nitrogen and other gases as may be required to operate a Liquefaction Train.

MMBtu” means one million British Thermal Units.

MMSCFD” means Million Standard Cubic Foot per Day.

Month N” means the calendar month during which the Notice to Proceed Date occurs or a subsequent month, as applicable, during which Work is performed.

Month N+2” has the meaning set forth in Section 6.3.1.

Monthly Progress Report” has the meaning set forth in Section 13.3.

MTPA” means million Tonnes of LNG per annum.

MW” means one (1) megawatt or one million (1,000,000) watts.

Net LNG Sales Proceeds” has the meaning set forth in Section 7.1.2.

Non-Reimbursable Costs” has the meaning set forth in Exhibit B-1.

Notice” means a written communication from one Party to another Party required or permitted by this Agreement, conforming to the requirements of Article 38.

Notice of Contract” has the meaning set forth in Section 3.8.56.

 

16


Notice of Dispute” has the meaning set forth in Section 36.1.1.

Notice to Proceed” has the meaning set forth in Section 4.1.1.

Notice to Proceed Date” has the meaning set forth in Section 4.1.1.

Open Cost Items” has the meaning set forth in Section 6.1.3.

Original Agreement” has the meaning set forth in the recitals.

Owner” has the meaning set forth in the introductory paragraph hereof, and includes its legal successors and those permitted assigns as may be designated by Owner, in writing, pursuant to the terms of this Agreement.

Owner Caused Delay” means any delay in the performance and completion of the Work by the Applicable Deadline that is directly and demonstrably caused by an act, omission or failure by Owner, Owner Contractors or any party for whom Owner is responsible hereunder, to perform its obligations hereunder including as a result of: (i) the failure of Owner to obtain a Permit that Owner is required to obtain hereunder; (ii) the failure of the Owner Furnished Equipment and Materials to perform in accordance with the requirements of the Owner Contract(s) pursuant to which such Owner Furnished Equipment and Materials were purchased by Owner; (iii) the failure by Owner to perform the Owner Scope of Work, including the supply of the Owner Furnished Equipment and Materials, on the agreed schedule therefor; (iv) the failure of BH to declare “Ready for Test” (as that term is defined in the LTS PO) in relation to the liquefaction trains comprising any LNG Production System within [***] days of Contractor achieving LNG Production System RFSU in respect of such LNG Production System, as described in Section 18.2.1 (a “BH Testing Delay”); (v) the failure of an Owner Contractor to timely perform its obligations under its respective Owner Contract(s); or (vi) the failure of Owner to approve change orders or claim settlements with Subcontractors and Agent For Contractors in accordance with this Agreement, which failure actually, demonstrably and adversely affects the Critical Path; provided, however, that, notwithstanding the foregoing, “Owner Caused Delay” does not include: (a) any act or omission (except as to item (vi) above) that is permitted under, and is taken or caused in accordance with, the terms of this Agreement; (b) any act or omission of Owner acting under or in accordance with any written instructions from Contractor or the Contractor’s Representative; or (c) any act, omission or failure by Owner, Owner Contractors or any party for whom Owner is responsible that does not affect the Critical Path (except with respect to (iv) above, in which case Contractor is entitled to a day for day extension as described in Section 12.1.1).

Owner Contractor” means any party to an Owner Contract (other than Owner). For the avoidance of doubt, the term Owner Contractor does not include Agent For Contractors.

Owner Contracts” means:

(a) the Construction Agreement relating to Marine Works, dated as of October 8, 2021, between Owner and Weeks-Massman, a Joint Venture;

 

17


(b) the Construction Agreement relating to Construction Dock and Marine Offloading Facilities, dated as of August 19, 2020, between Owner and Weeks-Massman, a Joint Venture;

(c) the Construction Agreement relating to a Storm Surge Wall, dated as of August 19, 2020, between Owner and Weeks-Massman, a Joint Venture;

(d) the LTS PO;

(e) the PIS PO;

(f) the LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 1), dated as of April 12, 2019, by and between CB&I LLC and Owner;

(g) the Amended and Restated Engineering and Procurement Agreement (Phase 1), dated as of September 27, 2021, by and between UOP LLC and Owner; and

(h) the Field Services Agreement.

Owner Designees” means the Independent Engineer, Owner’s Representative, any Affiliate of Owner so designated in writing by Owner and all other consultants, contractors, agents or representatives Owner or its Affiliate employs or appoints in connection with the performance of Owner’s rights and obligations under this Agreement. For the avoidance of doubt, the term Owner Designees does not include any Agent For Contractor.

Owner Furnished Equipment and Materials” means the equipment, materials or components of the Facility that are to be furnished or procured by Owner or the Owner Contractors under the Owner Contracts as part of the Owner Scope of Work.

Owner Indemnitees ” means Owner, Owner’s Representatives, the Lenders, the Independent Engineer and all Affiliates, officers, directors, employees and agents thereof.

Owner Protocols ” means the written protocols for the Contractor’s operation of the Facility during the period commencing on the LNG Production System Substantial Completion Date for the first LNG Production System to achieve LNG Production System Substantial Completion and ending on the Facility Substantial Completion Date, as described in Exhibit T.

Owner Scope of Work ” means the services and other activities performed by or on behalf of Owner that are specifically identified as the “Owner Scope of Work” in Exhibit A. For the avoidance of doubt, the Owner Scope of Work does not include the Agent For Contracts Work.

Owner Standards” unless otherwise specified in Exhibit A, means those sound and prudent practices, methods, specifications or standards of design, engineering, construction, performance, safety, workmanship, equipment and components prudently and generally engaged in or observed by the majority of the professional engineering and construction contractors in the LNG and electric power industry in the United States of America for similar types of LNG export and liquefaction facilities and power generation facilities that at a particular time, in the exercise of reasonable judgment, would have been expected to accomplish the desired result in a manner

 

18


consistent with applicable Laws, Applicable Codes and Standards, Permits, reliability, health and safety, and environmental protection and local conditions, but such standards are not limited to the best or optimum practice or method to the exclusion of all others. Without limiting the foregoing, the Facility or any portion thereof or any technical specifications shall not be required to meet any specifications less stringent than the specifications set forth herein. Owner Standards are not intended to be limited to the optimum practices, methods, or standards to the exclusion of all others, but rather to be a spectrum of reasonable and prudent practices, methods, and standards employed by firms in the engineering and construction industry familiar with building comparable facilities on the Gulf Coast of the United States of America.

Owner’s Representative” means Owner’s employee or representative designated by Owner pursuant to Section 3.7.3.

Parties” means Owner and Contractor collectively, and “Party” means Owner or Contractor, individually, as applicable.

Payment Bond” means the Performance and Payment Bond described in Section 9.2.3.

Performance Bond” means the Performance and Payment Bond described in Section

9.2.2.

Performance and Payment Bonds” has the meaning set forth in Section 9.2.1.

Performance Security” means the security provided by Contractor to Owner in the form of the (a) Performance and Payment Bonds and (b) the Contractor Guarantees.

Performance Tests” has the meaning set forth in Exhibit R.

Permit” means any authorization, consent, approval, license, ruling, permit, exemption, filing, variance, order, judgment, decree, publication, condition, notice to, declaration or registration of or with or regulation by or of any Government Authority relating to the acquisition, ownership, occupation, construction, Pre-Commissioning, Commissioning, testing, operation or maintenance of the Facility.

Permitted Liens” means materialmen’s, mechanics’, workers’, repairmen’s, employees’ or other similar liens filed by a Subcontractor arising in the ordinary course of business for amounts not yet due or for amounts being contested in good faith by appropriate proceedings, so long as, in the case of any such contest, (a) Contractor shall have posted or provided to Owner a letter of credit, bond (in form and substance acceptable to Owner) or other security reasonably satisfactory to Owner and the Independent Engineer in an amount equal to such contested lien and (b) such proceedings in Owner’s reasonable judgment shall not involve any danger of the sale, forfeiture or loss of any part of the Facility, title thereto or any interest therein and shall not interfere with the timely completion, use or disposition of the Facility.

Person” means an individual, a corporation, a limited liability company, an unincorporated organization, a partnership, a joint venture, an association, a trust or any other entity or organization, including a Government Authority.

 

19


 

Pipeline Contractor” means the Person engaged to engineer, procure and construct the Gator Express Pipeline.

Pipeline Tie Point(s)” means the point(s) where the systems of the Facility are interconnected with the Gator Express Pipeline, as more specifically described in Exhibit A.

PIS PO” means the Purchase Order Contract for the Sale of the Power Island System, dated as of February 26, 2021, between Owner and BH.

Power Plant” means (i) five (5) [***] gas turbines and associated generators, two (2) [***] steam turbines and associated generators, five (5) HRSG’s [***], two (2) air-cooled condensers, (ii) three (3) [***] gas turbines and associated generators relating to LPS4; and (iii) the associated pumps, piping, valves, instrumentation, electrical systems, and control systems, including any required auxiliary or ancillary equipment, as more specifically described in Exhibit A.

Pre-Approved Site Work” means the site preparation work so identified in Exhibit A.

Pre-Commercial Production Period” has the meaning set forth in Section 7.1.2.

Pre-Commissioning” means the checks, tests and calibrations set forth in Exhibit P and required to be performed as part of the Work prior to performing the Commissioning of an LNG Production System, including all applicable safety related and utility components being placed in service and made operational, completion of all function testing/static commissioning activities that do not involve the introduction of hydrocarbons into systems, such as loop checks, operating control and emergency actuated valves, panel function tests, energizing electrical equipment and running motors without loads, all carried out on a single discipline basis, typically by system/subsystem, and the completion of all ‘A’ and ‘B’ inspection and test records and agreed punch lists.

Pre-Existing Hazardous Substance” means a Hazardous Substance that existed or was present on, at or under the Job Site on or before the Notice to Proceed Date.

Pre-Treatment System” means an acid gas treating, dehydration and regeneration system, and heavy hydrocarbon removal system, as further described in Exhibit A.

Project Schedule” means the schedule for the performance of the Work developed, delivered and maintained in accordance with Exhibits D and E.

Punch List Items” means those minor items of the Work identified by Owner or Contractor as requiring completion or correction prior to Final Completion, which items do not affect the performance or safe and continuous operation of an LNG Production System or the Facility.

Qualified Surety” means a U.S. bank, insurance company, or other financial institution which is rated at least “A” by Standard & Poor’s Ratings Group, Inc. (or a comparable rating from another internationally recognized ratings agency).

 

20


 

Quality Management Plan” has the meaning set forth in Section 10.1.

Ready for Commissioning Certificate” means the certificate provided to Owner by Contractor, after LNG Production System Mechanical Completion and completion of Pre-Commissioning of an LNG Production System, certifying that such LNG Production System is ready for Commissioning.

Reimbursable Costs” means Direct Costs that are reimbursable to Contractor, as described in Exhibit B-1.

Reimbursable Work” means the Work, excluding the Corrective Work.

Release” means any emission, spill, seepage, leak, escape, leaching, discharge, injection, pumping, pouring, emptying, dumping, disposal, migration, or release of Hazardous Substances from any source into or upon the indoor or outdoor environment.

Relied Upon Information” has the meaning set forth in Exhibit M.

Representatives ” means, with respect to a Party, such Party’s Affiliates, directors, officers, and employees.

Request for Payment” means the Contractor’s monthly submission to Owner of all documentation and materials required by Section 6.3 requesting payment, which request for payment shall be in the form provided in Exhibit F-7.

Satellite Facility” means each site located in the vicinity of the Job Site that is jointly designated by Owner and Contractor to be utilized by Contractor and/or its Subcontractors for the positioning, storage and/or transshipment of certain equipment and materials necessary for the performance of the Work

Schedule Delay Liquidated Damages” means the LPS1 Schedule Delay Liquidated Damages, the LPS2 Schedule Delay Liquidated Damages, the LPS3 Schedule Delay Liquidated Damages, the LPS4 Schedule Delay Liquidated Damages and the Facility Schedule Delay Liquidated Damages.

SDN” has the meaning set forth in Section 40.1.1.

Second Restatement Date” has the meaning set forth in the introductory paragraph hereof.

“Senior Supervisory Personnel” means Contractor’s project director, project engineering manager, project construction manager and other Contractor personnel identified in Exhibit K.

Serial Defect” has the meaning set forth in Section 20.2.6.

Severe Injury” means an injury or accident that requires, or is reasonably likely to require, a formal admission to a hospital or clinic for care or treatment, excluding treatment solely in an urgent care center.

 

21


 

Shipping Information” has the meaning set forth in Section 3.10.

Spare Parts” has the meaning set forth in Section 3.9.1.

Subcontract” means an agreement (including a purchase order) (a) by Contractor with a Subcontractor for the supply of any equipment or materials or the performance of any portion of the Work or (b) by a Subcontractor with a lower tier of Subcontractor for the supply of any equipment or materials or the performance of any portion of the Work.

Subcontractor” means any Person (other than Contractor) that performs any portion of the Work, whether hired directly by Contractor, or by a Person hired by Contractor and including every tier of Subcontractor, sub-subcontractors, vendors, suppliers and so forth.

Surplus Construction Materials” has the meaning set forth in Section 3.8.15.

Suspension Notice” means a notice of suspension provided by Owner to Contractor in accordance with Section 17.1.1 or 17.1.2.

Suspension Period” has the meaning set forth in Section 17.1.1.

System Turnover Package” means those binders defined by the individual system process and instrument diagrams (P&ID) and electrical single line diagrams in which Contractor compiles all relevant quality assurance and quality control test results which show that the system and its components were installed and tested in full conformance with the design drawings, vendor requirements, Owner Standards and this Agreement.

Tank One” means the LNG Storage Tank so identified on the plot plan provided in Exhibit A.

Tank Two” means the LNG Storage Tank so identified on the plot plan provided in Exhibit A.

Target Price” has the meaning set forth in Section 6.1.1.

Tax” means any present or future tax (including any stamp duty, income, payroll, sales, use, value added, consumption or goods and services tax), tariff, levy, impost, duty, charge, fee, deduction or withholding of whatever nature, including any such income tax, payroll tax, value added tax, sales tax, stamp tax, customs duty, import duty, export duty, withholding tax, excise tax, property tax, registration fee or license, water tax, sanitary tax, lighting tax or environmental, energy or fuel tax, which is levied, collected, assessed or imposed by a Government Authority at any time, and any interest, penalty, charge, fee or other amount imposed, collected, withheld, assessed or made on or in respect of any of the above.

Third Party” means any party other than an Owner Indemnitee, a Contractor Indemnitee, an Owner Contractors or an Owner Contractors’ subcontractors. For the avoidance of doubt, the term Third Party does not include any Agent For Contractor.

Tonne” means metric ton and is defined as 2,204.6 lbs.

 

22


 

Total Cost Exclusions” means for the purposes of Section 8.1.2: (i) [***]; (ii) Taxes, if paid by Contractor which will then be reimbursed by Owner, unless such Taxes constitute Non-Reimbursable Costs; (iii) costs incurred by Contractor or assigned by Owner with respect to Owner Furnished Equipment and Materials, including with respect to defects or deficiencies, or lack of performance of, Owner Furnished Equipment and Materials; (iv) uninsured losses and deductibles arising under the Construction and Erection All Risk Insurance Policy, Owner Controlled Insurance Program for Commercial General Liability Policy, marine cargo, and any permanent property insurance policy, each procured by Owner; (v) Direct Costs paid to or paid by Contractor for Work subject to a claim against the Builder’s Risk Insurance Policy, Owner Controlled Insurance Program for Commercial General Liability Policy Marine Cargo, or Permanent Property Insurance policies; (vi) amounts reimbursed or credited to Contractor by Subcontractors (including back charges for Work performed by Contractor to complete Subcontractor work or remedy Subcontractor Defects and Deficiencies, liquidated damages or otherwise); and (vii) any other cost expressed to be excluded from the calculation of Total Costs hereunder; provided that, in the case of Defects or Deficiencies, the Direct Costs paid to Contractor or costs incurred by Owner in order to correct the Defects or Deficiencies in accordance with Section 20.5 shall be included in the calculation of “Total Costs”.

Total Costs” has the meaning set forth in Section 8.1.2.

Treated Gas” means natural gas that has been treated (through removal of compounds or otherwise) for quality to make it suitable for feed into a Liquefaction Train.

U.S.” has the meaning set forth in Section 40.3.1.

UOP” means UOP LLC or any of its Affiliates.

Warranties” has the meaning set forth in Section 20.2.7.

Warranty Period” means the period that commences on the relevant LNG Production System Substantial Completion Date and ends [***] after the Facility Substantial Completion Date, subject to any extension thereof pursuant to Sections 20.2.6 and 20.4.

Willful Misconduct” means in relation to the Person concerned, a deliberate act or omission not justifiable by any circumstances that is likely to cause foreseeable injury or harm; but shall not include any unintentional act, omission or mistake made by any Person.

Work” means all acts or actions required to be performed by Contractor and its Subcontractors under this Agreement or by the Agent For Contractors, or necessary for Contractor to complete its obligations hereunder, including the integration and installation of Owner Furnished Equipment and Materials and the design and engineering (including verification of the integration design for purpose of confirming the Facility Performance Tests requirements and undertaking of a debottlenecking or plant integration constraint study of the Facility for the purpose of maximizing the performance of the Facility, and such other studies, as applicable, described in Exhibit A or as Owner may reasonably request, and implementing the recommendations of such studies), procurement, manufacturing, preservation, packing and transportation, construction, training, erection, testing, Pre-Commissioning, Commissioning, start-

 

23


 

up, operation, and guaranteeing of the Facility in accordance with Article 15, whether at the Job Site or elsewhere, until Final Completion and satisfaction of Contractor’s warranty obligations during the Warranty Period, as more fully described in Exhibit A and this Agreement, and such other incidental acts as may be necessary to provide Owner with a fully operational and integrated Facility which successfully passes the Performance Tests, at least meets the Owner Standards and otherwise satisfies the conditions set forth herein. The term “Work” shall also include providing security of the Job Site and construction management services relating to the scheduling and coordination of the work and services performed by the Owner Contractors under the Owner Contracts and the administration of the performance by each Owner Contractor of its obligations of the relevant Owner Contract(s). Notwithstanding the foregoing, the term “Work” shall not include: (i) the supply or performance (except as it relates to installation or integration or as described in the immediately preceding sentence) of the Owner Furnished Equipment and Materials; (ii) the performance of the Owner Scope of Work; or (iii) any other obligation of Owner specifically described herein.

 

2.

AGREEMENT; EXHIBITS; CONFLICTS.

 

2.1

LANGUAGE OF AGREEMENT.

This Agreement and all documentation to be supplied hereunder (including the operation and maintenance manuals which Contractor provides to Owner pursuant to Section 3.8.6 as well as all warranties provided hereunder) shall be in the English language. All dimensions and properties set forth herein, any Exhibit hereto and any Drawings and Specifications shall be specified in English or U.S. customary units unless otherwise approved by Owner or agreed with Owner as a normal practice with respect to LNG liquefaction facility or power plant design. Words not otherwise defined herein that have well-known and generally accepted technical or trade meanings are used herein in accordance with such recognized meanings in the United States of America.

 

2.2

PRECEDENCE OF AGREEMENT.

2.2.1 Each Party shall promptly notify the other in writing of any discovered conflict or inconsistency among any of the Exhibits or between any Exhibit and the body of this Agreement. In the event of any conflict between provisions of Sections of this Agreement, Drawings and Specifications and Exhibits, the following order of precedence for construction and interpretation shall apply unless the Parties otherwise agree:

(a) amendments, addenda or other modifications to this Agreement (including Change Orders) duly signed and issued after the Second Restatement Date, with those of a later date having precedence over those of an earlier date;

(b) Sections of this Agreement;

(c) Exhibit R – Demonstration Tests and Performance Tests;

(d) Exhibit C – Contractor Rates;

(e) Exhibit B – Compensation;

 

24


 

(f) Exhibit D – Form of Project Schedule and Milestones;

(g) Exhibit A – Scope of Work; Applicable Codes and Standards;

(h) the remaining Exhibits to this Agreement; and

(i) Drawings and Specifications.

2.2.2 Subject to Section 2.2.1, in the event of a conflict among or within any of the levels set forth in Section 2.2.1, or between the documents described in Section 2.2.1 and any Agent For Contract, the more stringent provision shall prevail. Notwithstanding the above, the provisions of this Agreement, including all Exhibits, shall be wherever possible construed as complementary rather than conflicting. Silence regarding a matter shall not constitute a conflict with another component of the Agreement that specifically addresses such matter.

 

2.3

INTERPRETATION.

Unless the context otherwise requires:

2.3.1 Words singular and plural in number will be deemed to include the other and pronouns having a masculine or feminine gender will be deemed to include the other;

2.3.2 In respect of general oversight of the Work, review of any Drawings and Specifications, access to the Job Site and the Work and all other similar rights of Owner, the term Owner shall be deemed to include Owner’s Representative and its designated staff;

2.3.3 Any reference to this Agreement or any other contract or agreement entered into by Owner in respect of the Facility means such agreement and all schedules, exhibits and attachments thereto as may be amended, supplemented or otherwise modified and in effect from time to time, and shall include a reference to any document which amends, modifies or supplements it, or is entered into, made or given pursuant to or in accordance with its terms;

2.3.4 The terms “hereof,” “herein,” “hereby,” “hereto”, “hereunder” and similar words refer to this entire Agreement and not any particular Section, subsection or other subdivision of, or Exhibit, appendix or schedule to, this Agreement;

2.3.5 The terms “include” and “including” shall be construed as being at all times followed by the words “without limitation” or “but not limited to” unless the context specifically indicates otherwise;

2.3.6 The words “as more fully described in” or words and phrases of similar meaning are not intended to be, nor should be construed to limit in any way, the obligations of Contractor to provide Owner with a fully operational Facility pursuant to the terms hereof;

2.3.7 References to “Article,” “Section” or “Exhibit” are to this Agreement unless specified otherwise;

 

25


 

2.3.8 References herein to the terms, provisions or requirements of this Agreement shall be deemed to include, with respect to Contractor’s obligations to perform the Work, the terms, provisions and requirements of the Agent For Contracts (excluding payment obligations);

2.3.9 References to Contractor’s personnel include employees of a JV Member or its Affiliate assigned to the performance of the Work;

2.3.10 References to any law, statute, rule, regulation, notification or statutory provision (including Laws and Permits) shall be construed as a reference to the same as it may have been, or may from time to time be, amended, modified or re-enacted;

2.3.11 References to “jointly and severally” and “joint and several basis” shall, if construed under the laws of the State of Louisiana, be construed to describe a solidary obligation between the obligors to each obligee in solido;

2.3.12 Any reference to “KBR” in Attachment 4 or Attachment 5 of Exhibit A or Exhibit E shall be treated as a reference to “Contractor”;

2.3.13 References to any Person shall be construed as a reference to such Person’s successors and permitted assigns; and

2.3.14 The word “or” will have the inclusive meaning represented by the phrase “and/or”.

 

2.4

NEGOTIATION AND DOCUMENTATION OF THIS AGREEMENT.

Each of the Parties acknowledges and agrees that it has had the opportunity to have its legal counsel review this Agreement and participate in the joint negotiation and documentation of this Agreement, and that it is fully familiar with each of the provisions of this Agreement and the effect thereof. Accordingly, each Party irrevocably waives the benefit of any rule of construction that disfavors the drafting party and any defense related thereto.

 

3.

GENERAL PROVISIONS.

 

3.1

WORK TO BE PERFORMED.

3.1.1 Owner hereby engages and is relying upon Contractor to perform the Work in accordance with Exhibit A and the other requirements of this Agreement, and Contractor acknowledges such reliance and accepts such engagement. Owner and Contractor agree that Contractor’s obligation under this Agreement is to complete the Work so that the Facility successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the other provisions of this Agreement, including achieving Facility Mechanical Completion, Facility Substantial Completion, and Final Completion within the time and for the purpose designated herein, and to do and furnish everything incidental and necessary in connection therewith.

3.1.2 Prior to the execution of this Agreement, Contractor performed engineering, cost estimating and related services and developed, provided or verified all of the information that forms the scope of Work set forth in Exhibit A for the purpose of verifying that such information

 

26


 

is adequate for, and Contractor represents and warrants to Owner that the scope of Work set forth in Exhibit A includes all the necessary obligations, including integration, as applicable, that are required to be performed by Contractor and Owner in order for, the Facility to operate in accordance with the terms of this Agreement and to satisfy the Applicable Codes and Standards, applicable Laws, Owner Standards and Permits and successfully pass the Performance Tests and meet or exceed the requirements set forth in Exhibit A. Items need not be specifically listed herein or in Exhibit A in order to be deemed to be items within the scope of the Work. It is understood that Contractor is better qualified to list exclusions than Owner is to list inclusions. Therefore, except for the supply of Owner Furnished Equipment and Materials and performance of the Owner Scope of Work, any item indicated herein, inferable therefrom, incidental thereto or required in accordance with any Law, Permits or Applicable Codes and Standards is to be considered as part of the Work. In addition, the Work includes all that should be included and all that would be customarily included within the general scope of the Work in order to complete the Facility (excluding the supply of Owner Furnished Equipment and Materials and performance of the Owner Scope of Work) according to the requirements of this Agreement, including Applicable Codes and Standards, applicable Laws, the requirements for the Performance Tests and the Permits. As a result, Contractor hereby waives any and all claims for an increase in the Target Price or an extension of any Applicable Deadline based, in whole or in part, upon an assertion that Contractor’s scope of Work in Exhibit A and as otherwise provided in the Exhibits was insufficient and did not include a certain license, technical assistance, engineering, assembly, construction, service, labor, material, equipment, operation or management beyond the scope of the Work when such license, technical assistance, engineering, assembly, construction, service, labor, material, equipment, operation or management is indicated in Exhibit A, this Agreement or any other Exhibit, the Drawings and Specifications or other instruments of service prepared by Contractor or a Subcontractor in connection with this Agreement reasonably inferable therefrom, incidental thereto, required in accordance with any Applicable Codes and Standards, applicable Law, Permits or otherwise necessary in order to complete the Facility in accordance with and subject to the requirements of this Agreement.

3.1.3 Time is of the essence with respect to Contractor’s achievement of each Applicable Deadline (other than the Final Completion Deadline).

 

3.2

GENERAL OVERSIGHT AND ACCESS.

3.2.1 Owner and the Owner Designees shall at all times have access to the Job Site and the Work wherever it is in preparation and progress and Contractor shall provide reasonable facilities for such access. Owner and the Owner Designees shall comply with the Contractor’s reasonable safety and access procedures. Each of Owner and the Owner Designees may (a) make inquiries of Contractor and visit the Job Site and Contractor’s work facilities and/or (b) maintain staff on the Job Site, in each case, to (i) familiarize itself with the progress and quality of the Work, (ii) determine if the Work is proceeding in accordance with this Agreement and (iii) witness and/or participate in Pre-Commissioning and Commissioning and any tests (including the Performance Tests) and inspections of the Materials and any other component of the Facility.

3.2.2 Subject to the limitations of the immediately following sentence, Owner Contractors and the Pipeline Contractor shall at all times have access to the entire Job Site wherever it is in preparation and progress, and Contractor shall provide reasonable facilities for such access. Owner Contractors and the Pipeline Contractor shall comply with the Contractor’s reasonable safety and access procedures for access to and when present on the Job Site.

 

27


 

3.3

JOB SITE CONDITIONS.

Except as otherwise provided herein, Contractor has had sufficient opportunity to review (a) information provided to it by Owner as set forth in Exhibit M and Exhibit N, (b) each Agent For Contract and (c) the information it has developed on its own (excluding sub-surface testing), and it is sufficiently informed about the Job Site and surrounding locations, including all visible surface conditions, to the full extent it deems necessary for the performance of the Work and is familiar with and has satisfied itself with respect to (i) the nature and location of the Work and (ii) the general and local conditions with respect to (A) environment, (B) transportation (including to the Job Site and within the Job Site), (C) access, (D) the use, handling, storage and disposal of Hazardous Substances and other wastes brought to the Job Site by Contractor, any Subcontractor or any Agent For Contractor, (E) the use, handling and storage of Materials, (F) the availability and quality of temporary construction electric power, (G) the availability and surface condition of roads, climatic conditions and seasons (except to the extent any such climatic conditions constitutes a Force Majeure Event), (H) physical and environmental surface conditions at the Job Site and the surrounding area as a whole, (I) topography and ground surface conditions, (J) nature and quantity of surface materials to be encountered, (K) location of underground utilities existing prior to the Effective Date as disclosed to Contractor by Owner in writing in Exhibit M or Exhibit N, (L) construction equipment, and other equipment, supplies and facilities needed prior to and during performance of Contractor’s obligations under this Agreement and (M) the availability and quality of workers, laborers and Subcontractors (the foregoing, collectively, the “Job Site Conditions”). Without prejudice to Article 12 with respect to Change Orders, Contractor expressly waives any claims for any increase in the Target Price or adjustment to the Project Schedule in connection with the Job Site Conditions.

 

3.4

OWNER NOT RESPONSIBLE FOR ACTS OF CONTRACTOR; CONTRACTOR NOT RESPONSIBLE FOR OWNER SCOPE OF WORK.

3.4.1 Other than with respect to means, methods, sequences, procedures and techniques of construction (for which Contractor shall have sole responsibility), Contractor will comply with reasonable instructions and requests of Owner or Owner’s Representative which are consistent with the Work, the requirements set forth in Exhibit A, and achievement of the Applicable Deadlines and successfully passing the Performance Tests; provided that Contractor will comply with reasonable technical instructions and requests of BH and UOP in connection with the unloading, transport, installation, connection, start-up, commissioning and operation of any Owner Furnished Equipment and Materials supplied by BH and UOP. Owner will not be responsible for construction or manufacturing means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, and Owner will not be responsible for Contractor’s failure to carry out the Work in accordance with this Agreement, but this Section 3.4.1 shall not be deemed to otherwise modify Owner’s obligations with respect to Reimbursable Costs, Contractor’s G&A and Contractor’s Margin otherwise due and payable hereunder. Owner will not be responsible for the acts or omissions of Contractor, any Subcontractor, any Agent For Contractor or any of their agents or employees, or any other Persons performing any of the Work on behalf of Contractor or any Subcontractor or Agent For Contractor. No inspection, or failure to inspect, by Owner, Owner’s Representative or the Independent Engineer shall be a waiver of Contractor’s obligations, or be construed as approval or acceptance of the Work or any part thereof.

 

28


 

3.4.2 Except as set forth in Exhibit A, Contractor will not be responsible for construction or manufacturing means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Owner Scope of Work, and Contractor will not be responsible for Owner’s or any Owner Contractor’s failure to carry out the Owner Scope of Work, the supply or performance of the Owner Furnished Equipment and Materials (except to the extent expressly identified as part of the Work). Contractor will not be responsible for the acts or omissions of Owner, any Owner Contractor, or any of their agents or employees, or any other Persons performing any of the Owner Scope of Work.

 

3.5

EFFECT OF AND TIME FOR OWNER REVIEW OF DOCUMENTS.

Inspection, review or comment by Owner or the Independent Engineer (or the failure to do so) with respect to any Subcontract, Drawings and Specifications or other documents, or any other Work or services performed by Contractor or any Subcontractor or Agent For Contractor, shall not in any way affect or reduce any of the Contractor’s obligations to complete the Work so that the Facility successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the other provisions of this Agreement or in any way affect the Target Price. Contractor shall prepare Drawings and Specifications and submit them to Owner and the Independent Engineer at least thirty (30) days before the date on which the Work described in them is to be performed. Upon the written request of the Owner, Contractor shall provide to the Owner any information reasonably requested in connection with the Drawings and Specifications. Owner may, but is not obligated to, have the Independent Engineer review the Drawings and Specifications submitted by Contractor. Contractor shall discuss and answer any inquiries concerning the Drawings and Specifications with Owner or the Independent Engineer. Owner may reject or amend the Drawings and Specifications that are not in accordance with the requirements set forth in Exhibit A, Owner Standards and the other provisions of this Agreement by sending disapproval that states in reasonable detail the reason(s) for such disapproval or by sending revisions, in each case within fifteen (15) days from receipt of Drawings and Specifications.

 

3.6

CLAIMS UPON FAILURE OF MATERIAL.

In accepting the Work performed and Materials supplied, assembled or installed by Contractor, Owner assumes no responsibility for injury or claims resulting from (a) failure of such Work and Materials to comply with applicable Laws, Permits, safety requirements, Applicable Codes and Standards and Owner Standards, (b) Contractor’s failure to unload, transport, integrate, install, connect, start-up, commission or operate all Owner Furnished Equipment and Materials in accordance with applicable Laws, Permits, safety requirements, Applicable Codes and Standards, Owner Standards, (provided that the Owner Standards, are consistent with applicable Laws, Permits, safety requirements, and Applicable Codes and Standards), (c) Defects or Deficiencies (other than Owner’s obligation hereunder to pay the Reimbursable Costs, Contractor’s G&A and Contractor’s Margin associated with Defects or Deficiencies) or (d) Corrective Work. Contractor’s performance of the Work shall include the provision of all necessary permanent safety devices in accordance with the terms hereof, Owner Standards and as required by Government Authority or applicable safety codes.

 

29


 

3.7

RESPONSIBILITIES OF OWNER.

Without limiting the requirements of any other provision of this Agreement, Owner shall:

3.7.1 furnish nonexclusive access to the Job Site to Contractor from and after the time of the issuance of the Notice to Proceed or, if expressly authorized in the Limited Notice to Proceed, the time of issuance of the Limited Notice to Proceed;

3.7.2 provide legal rights for ingress to and egress from the Job Site for Contractor and its Subcontractors for the performance of the Work and for the Owner Contractors and the Pipeline Contractor, consistent with Owner’s property rights with respect to the Job Site. During the progress of the Work, it will be necessary for Owner and Owner Contractors to work in or about the Job Site. In accordance with Section 3.2.2, Contractor shall afford such Owner Contractors reasonable access through and across the Job Site so as to not materially adversely interfere with or impede the progress and execution of work performed by such Owner Contractors in or about the Job Site. Contractor shall exercise good faith cooperation with the Owner Contractors and the Pipeline Contractor;

3.7.3 designate a single individual as Owner’s Representative to act as a single point of contact for Contractor, Owner Contractors and the Pipeline Contractor with respect to the prosecution of the Work. Any proposal, inspection, examination, testing, consent, approval or similar act by Owner’s Representative (including absence of disapproval) shall not relieve Contractor from any responsibility, including responsibility for its errors, omissions, discrepancies and non-compliance with the terms of this Agreement. Owner shall have the right to change the Owner’s Representative and/or modify his/her scope of responsibilities upon reasonable notice to Contractor. The Owner’s Representative shall be available at the Job Site and elsewhere, when reasonably required, at all reasonable times for consultation and, if absent, shall designate a suitable alternate to act as Owner’s Representative during such absence;

3.7.4 furnish personnel in accordance with Exhibit G for training, testing, operation and maintenance of the Facility, which personnel shall possess experience and education qualifications which in Owner’s determination are appropriate to permit achievement of the training objective;

3.7.5 with Contractor’s assistance, obtain or cause to be obtained in a timely manner the Permits listed in Exhibit L that are identified as Owner Permits (excluding for the avoidance of doubt the Permits set forth in Exhibit L that are identified as Contractor Permits) and any other Permit required under applicable Law to be obtained by it in connection with the operation of the Facility. Upon receipt of any such Permit, Owner shall promptly provide a copy of such Permit to Contractor. In addition, Owner shall cooperate with Contractor in obtaining any Permit required to be obtained by Contractor in the performance of the Work. Contractor shall provide information reasonably requested by Owner to support Owner’s prosecution of any pending application listed in Exhibit L in respect to the Work and shall perform the Work in compliance with all of the terms and conditions of each of the foregoing Permits. Following Owner’s request, Contractor, on behalf of either Owner or itself, shall timely prepare and file all progress and other reports and any amendments as may be required by or in connection with said Permits and shall otherwise coordinate with any relevant Government Authority as requested by Owner;

 

30


 

3.7.6 obtain, provide and pay for the supply of (i) Feed Gas in accordance with Exhibit A and with the Feed Gas schedule prepared by Contractor in accordance with Section 3.8.11, (ii) [***] MW of electricity from the electrical utility grid, (iii) [***] gallons/day potable water as required for construction activities for the Work, (iv) improvement of the Job Site “fastlands” drainage system and pumping station to provide drainage of the Job Site during construction without standing water and (v) relocation of power and utility lines along Louisiana State Highway 23 in accordance with the Project Schedule;

3.7.7 (a) supply and, except as otherwise required in Exhibit A, deliver or cause to be delivered to the Job Site or a Satellite Facility, as applicable, all of the Owner Furnished Equipment and Materials to be incorporated into the Facility, (b) cause Owner Contractors to correct, repair, or replace all defects and deficiencies in Owner Furnished Equipment and Materials, (c) perform or cause to be performed the Owner Scope of Work, (d) with respect to Owner Furnished Equipment and Materials manufactured outside of the United States, cause such Owner Furnished Equipment and Materials to clear U.S. customs and Owner or Owner Contractor to be designated as the importer of record, in each case, in accordance with the requirements set forth in Exhibit A, applicable Law, Applicable Codes and Standards and the Permits; and (e) provide, or cause to be provided, relevant information and deliverables including, as applicable, system turnover packages from Owner Contractors that are obtainable under the Owner Contracts, as reasonably requested and to the extent not otherwise available to Contractor in the performance of its obligations hereunder;

3.7.8 during the period commencing on the LPS1 Substantial Completion Date and ending upon the Facility Substantial Completion Date, operate and maintain each LNG Production System Handover Package for which it has assumed care, custody and control hereunder in accordance with applicable Law, Permits, and operation and maintenance manuals provided by Contractor and Owner Contractors; and

3.7.9 obtain and maintain the insurance set forth in Section 26.3.

 

3.8

RESPONSIBILITIES OF CONTRACTOR.

Without limiting the requirements of any other provision of this Agreement, Contractor shall:

3.8.1 prosecute the Work continuously and diligently in accordance with Owner Standards, all applicable Laws, Permits, Applicable Codes and Standards and in accordance with the Project Schedule, using only qualified and competent personnel, and complete the Work so that the Facility successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the provisions of this Agreement;

3.8.2 ensure that all labor performing at the Job Site will be properly tooled, fully trained and qualified to safely perform the Work in accordance with applicable Law, Permits and Owner Standards;

 

31


 

3.8.3 perform and furnish the Work, including designing, engineering, procuring, manufacturing, packing and transporting, constructing, warranting, Pre-Commissioning, Commissioning, testing, training and directing of operating and maintenance personnel (including the personnel of Owner or its Affiliate) until Facility Substantial Completion, and guaranteeing performance of the Work in accordance with the terms hereof, so that the Facility (a) meets the requirements of all applicable Permits and applicable Laws, (b) meets the requirements of Owner’s property rights with respect to the Job Site identified in Exhibit N, (c) successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the provisions of this Agreement, (d) meets the requirements of the Applicable Codes and Standards, (e) is safe and adequate for conditions of loading, conveying, storing, metering, liquefying and delivering Feed Gas and LNG, (f) can be operated in a manner consistent with the staffing levels specified in Exhibit Q, (g) is capable of complying with the Laws (including Environmental Laws) issued by any Government Authority or other applicable entities set forth in Exhibit A and Exhibit L, and (h) comprises Materials which are new, are reasonable to maintain, have proven durability to withstand climatic conditions that could reasonably be expected to be experienced at the Job Site, are designed and manufactured in accordance with the requirements set forth in Exhibit A and are assembled and installed in accordance with manufacturer’s specifications and generally accepted standards for the design, manufacture, quality and assembly of such Materials;

3.8.4 obtain and maintain all Permits (including the Permits set forth in Exhibit L that are identified as Contractor Permits, but excluding the Permits set forth in Exhibit L that are identified as Owner Permits) and authorizations from any Government Authority, and administer all such Permits and authorizations required for (a) the design, engineering and construction of the Facility (or any portion thereof), (b) the procurement, handling, supply, shipment, transportation, installation, erection, direction of procurement and testing of the Materials, (c) the installation or integration of the Owner Furnished Equipment and Materials, and (d) the performance of all the Work. Contractor shall provide prompt assistance, information and documentation (including copies of any drawings and design documents) required or requested by Owner for the Work to enable Owner to obtain or modify, or cause to be obtained or modified, the Permits set forth in Exhibit L that are identified as Owner Permits. Contractor shall give Notice to Owner of all conflicts between the requirements set forth herein including Exhibit A and any Laws or Permits that come to the attention of Contractor or with the exercise of reasonable care should have come to the attention of Contractor. Contractor shall assist Owner in obtaining and maintaining all Permits that Owner must obtain pursuant to the terms hereof, including (i) providing information requested by Owner or requested or required by any Government Authority in the possession of, or reasonably obtainable by, Contractor, and (ii) identifying for Owner any Permits that Owner has not obtained, but which Contractor has reason to believe, after due inquiry, must be obtained by Owner for the Contractor’s performance of the Work and/or Owner’s ownership or operation of the Facility. Contractor will provide Owner a copy of its Louisiana Contractor’s License and Louisiana Engineering Firm Registration prior to commencement of the Work;

3.8.5 take full responsibility for the adequacy, stability, cleanliness and safety of Contractor’s (and Subcontractors’ and Agent For Contractors’) Job Site operations, of Contractor’s (and Subcontractors’ and Agent For Contractors’) methods of construction and of the Work, irrespective of any approval or consent by Owner, Owner’s Representative or the Independent Engineer;

 

32


 

3.8.6 pay the Taxes, insurance and bank charges incurred by Contractor or any Subcontractor arising from the performance of its duties under this Agreement;

3.8.7 have joint responsibility with Owner for coordination with Government Authorities, test laboratories and any other Person necessary to demonstrate the Facility’s compliance with all Permits and Laws;

3.8.8 be responsible for fines and penalties to the extent they constitute Non-Reimbursable Costs;

3.8.9 except as provided in Section 3.7.6 or Exhibit V, obtain all consumables (including construction fuel, construction electricity, water and other utilities and the supply and fill of lubricants, resins, chemicals and the refill and top-off of such lubricants and chemicals following any Performance Tests and other consumables as provided in Exhibit V) necessary for Contractor’s performance of the Work, and Owner’s or its Affiliate’s execution of the Performance Tests, during the period from commencement of the Work through the LNG Production System Substantial Completion Date for the corresponding LNG Production System Handover Package for which Owner assumes care, custody, and control;

3.8.10 obtain all internet access, telephone and radio usage necessary for Contractor’s performance of the Work and for each Owner Contractor’s performance of its respective services and work during the period from commencement of the Work through the Facility Substantial Completion Date;

3.8.11 determine sufficiently in advance the quantities of Feed Gas, in MMBtu, that will be required for each Day on which Commissioning activities and the Performance Tests in respect of each LNG Production System will be conducted as provided in Exhibit A and Exhibit R;

3.8.12 perform all Work necessary for the Feed Gas Interconnections specified in Exhibit A at the Facility and Pipeline Tie Point(s);

3.8.13 without limiting Owner’s obligations under Section 3.7.1, (a) until the earlier of the Facility Substantial Completion Date or termination of this Agreement, be responsible for the management of the Job Site (including (i) any construction routes between the road used to access the Job Site and the Job Site and within the Job Site boundaries, (ii) coordination of Subcontractors’ and Agent For Contractors’ activities and the management of all common areas within the Job Site so as to optimize Contractor’s, Subcontractors’ and Agent For Contractors’ performance, (iii) provide any signs or directions which they may consider necessary for the guidance of its staff, labor and others and (iv) maintain the Job Site at all times free of waste material and rubbish), (b) upon the earlier of Final Completion or termination of this Agreement, clear the Job Site of temporary structures, surplus items (unless Owner requests such surplus items be left at the Job Site), construction equipment and tools, (c) until the earlier of the Facility Substantial Completion Date or termination of this Agreement, provide all reasonable and necessary safeguards, including fencing, signs, security services, fire protection and the like, for the health, safety, security and protection of the Job Site, the Work and the Facility and of all Persons and property related thereto, and (d) until the earlier of the Facility Substantial Completion Date or termination of this Agreement, keep unauthorized Persons off of the Job Site and reconstruct, repair or replace Materials or property of Contractor which may be stolen or damaged by vandalism;

 

33


 

3.8.14 take all reasonable steps to protect the environment and to limit damage and nuisance to people and property resulting from pollution, construction noise and other results of the performance of the Work, and ensure that the Work and any Releases, including construction air emissions, surface discharges and effluent, from its performance of the Work shall be in compliance with all applicable Permits, Applicable Codes and Standards and Laws;

3.8.15 within ninety (90) days following the earlier of (a) Facility Substantial Completion Date or (b) earlier termination of this Agreement as provided herein, (i) assist Owner in preparing an inventory of all Materials (wherever located), special tools, construction aids and all other Contractor or Subcontractor materials, equipment, supplies purchased and used in connection with the Work (the “Surplus Construction Materials”), and (ii) transfer, or cause the transfer, of possession and title to Owner of all Surplus Construction Materials that Owner elects to take possession of by Notice to Contractor;

3.8.16 provide reports, information and data as will be necessary for Owner to maintain segregated accounts of the Work for Owner’s records where required by Law or generally accepted accounting principles in the United States of America. Such segregation will include separate accounting for expenditures with respect to buildings, land improvements, engineering and project management, Materials, Feed Gas Interconnections, Permit costs and Taxes paid by Contractor;

3.8.17 if (a) a Dispute under this Agreement arises in connection with a default or termination of this Agreement, or Owner’s obligation to pay certain Taxes hereunder, (b) a Change Order payment is to be determined on a cost-plus basis (at the then applicable labor rates then set forth in Exhibit C) or (c) the Work is accelerated pursuant to Section 16.3.2, then, in each case, grant to Owner sufficient audit rights with respect to all documentation pertaining thereto. Owner shall have the right to choose an independent certified public accounting firm to act as auditor for such an audit and the reasonable cost of any audit will be borne by the Party whose position is not substantially supported by the results of such audit. Audit data shall not be released by such auditor to Persons other than Contractor, Owner, the Independent Engineer, the Lenders or their respective employees and agents in connection with any such audit and Owner and Contractor shall treat such audit data as confidential, but shall not be precluded from using such audit data in any legal or arbitration proceedings arising under this Agreement in relation with the Dispute or Change Order;

3.8.18 make available to Owner and Owner Contractors at all times during the term hereof sufficient storage areas and personnel at each Satellite Facility for the unloading, handling, preservation, storage, loading and transportation of all Owner Furnished Equipment and Materials delivered to such Satellite Facility by an Owner Contractor, and not take or omit to take, and cause its Affiliates not to take or omit to take, any action with respect to such Satellite Facility that would prevent, impede, delay or otherwise hinder Contractor’s performance of the Work in accordance with this Agreement;

3.8.19 arrange and/or ensure the complete handling of all equipment, machinery, Materials and spare parts required for the Work, including the inspection, expediting, shipping and transport, unloading, receiving, storage and payment of all Taxes incurred in connection therewith, and arrange for proper safe keeping, handling, preservation, storage, maintenance and transportation at, to or from a Satellite Facility or the Job Site, as applicable, for such equipment, machinery, Materials and spare parts;

 

34


 

3.8.20 coordinate customs expediting and clearance services and logistics at the Job Site with a qualified company selected by Owner and perform all administrative formalities in connection therewith, including obtaining all approvals, certificates, documents and licenses which may be pertinent and/or necessary for Contractor’s equipment, machinery, Materials and spare parts required for the Work, all in a timely manner;

3.8.21 transport from each Satellite Facility to the Job Site all Owner Furnished Equipment and Materials delivered to such Satellite Facility in accordance with the Project Schedule;

3.8.22 provide for all temporary construction materials, equipment, supplies and facilities necessary for the performance of the Work;

3.8.23 upon Notice from Owner, replace (a) any Subcontractor who fails to perform its Subcontract obligations and (b) replace any of Contractor’s personnel, and cause any Subcontractor to replace its personnel, performing the Work if (i) Owner believes that such personnel are negligently performing the Work or that such personnel are creating a risk to the health and/or safety of Persons or property or (ii) Owner believes that such personnel are otherwise not performing the Work in accordance with Owner Standards or are creating a risk to the timely completion of the Work in accordance with this Agreement;

3.8.24 provide all special tools, construction/Commissioning spare parts and supplies required for operation of the LNG Production System (excluding all special tools, construction/Commissioning spare parts and supplies provided as part of the Owner Furnished Equipment and Materials) until the LNG Production System Substantial Completion Date, at which time all special tools and other supplies required for the operation of the LNG Production System that are supplied by Contractor shall be transferred to Owner in accordance with Section 3.8.15;

3.8.25 use only the entrance(s) to the Job Site designated by Owner and applicable Permits for ingress and egress of all personnel and vehicles and for the delivery of all Materials;

3.8.26 provide such assistance as is reasonably requested by Owner in dealing with the Lenders, the Independent Engineer or any Government Authority in any and all matters relating to the Work and the Facility; provided that no review, approval or disapproval by the Independent Engineer shall serve to reduce or limit the liability of Contractor hereunder;

3.8.27 cooperate with Owner’s Representative and designee and the Independent Engineer in the review of design materials, the conduct of inspections and Commissioning, and in any other matters hereunder relating to the Work and respond promptly to inquiries from Owner;

3.8.28 provide all operating instructions, procedures, data and manuals, spare parts manuals, integrated and coordinated operation and maintenance manuals and training aids in accordance with the Drawings and Specifications;

 

35


 

3.8.29 train and certify the operating and maintenance personnel in accordance with Exhibit G;

3.8.30 perform the Pre-Commissioning and Commissioning and direct the operation and maintenance personnel (including the personnel of Owner or its Affiliate) during Pre-Commissioning, Commissioning and execution of the Performance Tests in full accordance with the written operating instructions, the operations and maintenance manuals and the safety procedures;

3.8.31 obtain Owner’s prior written approval (which approval may be withheld in Owner’s sole discretion and for any reason) of the text of any announcement, publication, photograph or other type of communication concerning the Work prior to the dissemination or release of same by Contractor or its Subcontractors;

3.8.32 subject to Owner’s prior approval, designate the Contractor’s Representative who will have full responsibility for the prosecution of the Work and full authority under the JV Agreement to act for Contractor in respect of this Agreement and act as a single point of contact with Owner, Owner Contractors and Pipeline Contractor in all matters on behalf of Contractor. Upon the reasonable written request of Owner, Contractor shall promptly replace the Contractor’s Representative. Subject to Section 5.2, Contractor shall not replace the Contractor’s Representative without the prior written consent of Owner, which consent shall not be unreasonably withheld. The Contractor’s Representative shall be available at the Job Site and elsewhere, when reasonably required, at all reasonable times for consultation and, if absent, shall designate a suitable alternate to act as the Contractor’s Representative during such absence;

3.8.33 during the performance of the Work, maintain continuously at the Job Site adequate management, supervisory, administrative, security, safety, quality and technical personnel, to ensure expeditious and competent handling of all matters related to the Work, according to its determination of the staffing required for this purpose and Exhibit Y. Contractor shall designate the Key Personnel as set forth in Exhibit K;

3.8.34 provide such data, reports, certifications, certified copies of organizational documents, resolutions, incumbency certificates, audited financial statements, opinions of counsel and other documents or assistance as may be (a) reasonably requested by Owner, the Lenders or Owner’s title insurance providers with respect to the Financing or otherwise requested by Owner in connection with the performance of this Agreement or (b) requested or required by any Government Authority with respect to any Permits or regulatory filings;

3.8.35 advise Owner of negotiations with Major Subcontractors concerning the availability of improved warranties or guarantees related to major items of Materials to be incorporated into the Facility;

3.8.36 (a) cooperate with and provide information reasonably requested by Owner to support Owner in performing, or causing the performance of, the Owner Scope of Work and the delivery of the Owner Furnished Equipment and Materials to the Job Site or a Satellite Facility, as applicable; (b) receive, transport and unload at the Job Site, or a Satellite Facility or a storage yard designated by Owner for transshipment to the Job Site, all Owner Furnished Equipment and

 

36


 

Materials; (c) perform the construction management services relating to the scheduling and coordination of the work and services performed by the Owner Contractors under the Owner Contracts and the administration and reporting to Owner of the performance by each Owner Contractor of its obligations of the relevant Owner Contract(s); and (d) install and integrate the Owner Furnished Equipment and Materials into the Facility;

3.8.37 coordinate and perform the applicable portion of the Work under the oversight and direction of BH personnel that are present at the Job Site or a Satellite Facility pursuant to the Field Services Agreement;

3.8.38 maintain qualified personnel on the Job Site to consult with Owner regarding the operation and maintenance of the Facility (a) during Pre-Commissioning, Commissioning, start-up and testing of each LNG Production System and the Facility, (b) until successful completion of the training program required by Article 14 and (c) in accordance with the Warranty procedures set forth in Article 20 during the Warranty Period (which does not require Contractor to maintain personnel on the Job Site);

3.8.39 comply with the Warranty procedures set forth in Article 20;

3.8.40 in accordance with Article 39, cooperate with Owner in obtaining suitable Financing in accordance with the Lenders’ requirements;

3.8.41 provide complete Deliverables and follow them during the performance of the

Work;

3.8.42 prepare and keep up-to-date on a daily basis a complete set of red-lined “as-built” records of the execution of the Work, showing the “as-built” locations, sizes and details of the Work as executed, with cross references to relevant specifications and data sheets, which records shall be kept on the Job Site and shall be made available to Owner upon request;

3.8.43 prepare and submit to Owner “as-built” drawings (in accordance with Exhibit J) of the Work showing the process-related portions of the Work as executed. The “as-built” drawings shall be provided in their native file format, red-lined as the Work proceeds, and shall be submitted at least monthly (and more frequently as requested by Owner) to Owner for its inspection;

3.8.44 submit to Owner, within sixty (60) Days following the Facility Substantial Completion Date or upon termination of this Agreement, five (5) electronic files in a format designated by Owner, one (1) full-size original copy and six (6) printed copies of the relevant final “as-built drawings” (in accordance with Exhibit J) and any further construction documents relating to the Work reasonably requested by Owner, all prepared in accordance with this Agreement;

3.8.45 in accordance with Article 9, submit to Owner the applicable Performance Security;

3.8.46 refrain from bringing, and not permit or allow any Subcontractor, Agent For Contractor or other Person (other than an Owner Contractor acting in accordance with the relevant Owner Contract or the Pipeline Contractor) to bring, any Hazardous Substances on the Job Site and bear all responsibility and liability for such materials brought to the Job Site by Contractor, its Subcontractors or any Agent For Contractors; provided, however, that Contractor, Subcontractors

 

37


 

and Agent For Contractors may bring onto the Job Site such Hazardous Substances as are necessary to perform the Work so long as the same is done in compliance with applicable Laws, Permits, and Applicable Codes and Standards, and Contractor shall remain responsible and liable for all such Hazardous Substances. Contractor shall maintain an updated record and current inventory of all Hazardous Substances brought onto the Job Site or used by Contractor or any Subcontractors or Agent For Contractors in connection with the performance of the Work, which records shall identify types, quantities, location of storage, use and final disposition of such Hazardous Substances, and shall promptly make such file available to Owner at the Job Site upon preparation and any updates. If Contractor, any of its Subcontractors, or any Agent For Contractors cause or permit a Release of any Hazardous Substances brought to the Job Site by Contractor, its Subcontractors or Agent For Contractors on, at, under or from the Job Site, Contractor shall, at its sole cost and expense: (a) immediately notify Owner in writing; (b) comply with all applicable Laws, Permits and Applicable Codes and Standards and take all necessary steps to protect human health and the environment, and shall not exacerbate such condition; and (c) diligently proceed to take all necessary actions to clean up fully any contamination or impacts resulting therefrom. If Contractor, any of its Subcontractors, or any Agent For Contractor encounter a Release of any Hazardous Substances on, at, under or from the Job Site that is not caused or permitted by any of them or any Pre-Existing Hazardous Substances, Contractor shall: (a) immediately notify Owner in writing; (b) comply with all applicable Laws, Permits and Applicable Codes and Standards and take all necessary steps to protect human health and the environment, and shall not exacerbate such condition; and (c) diligently proceed to take all necessary actions to assist Owner’s efforts to clean up fully any contamination or impacts resulting therefrom;

3.8.47 during the performance of the Work, maintain an office at the Job Site, in a temporary or permanent structure that shall be subject to the approval of Owner, which shall serve as the offices for Contractor, Owner and Owner Contractors, and upon completion of the Work, leave such offices, which shall remain the property of Owner, in a clean condition satisfactory to Owner;

3.8.48 cooperate and cause the Subcontractors and Agent For Contractors to cooperate with Owner, Owner Contractors, the Pipeline Contractor and other unrelated contractors who may be working at or near the Job Site in accordance with the Project Schedule in order to assure that neither Contractor nor any of the Subcontractors nor any of the Agent For Contractors unreasonably hinders or increases or makes more difficult the work being done by or on behalf of Owner, the operation of the Facility and other unrelated contractors at or near the Job Site;

3.8.49 use reasonable efforts, and cause the Subcontractors and Agent For Contractors to use their reasonable efforts, to assist Owner in creating, assessing and carrying out programs which shall, during all phases of the Work, minimize the impacts on the host community caused by completion of the Work;

3.8.50 pay all Subcontractors in a timely fashion in accordance with the respective Subcontracts and provide Owner with Notice of any material dispute regarding the Work that is pending or threatened, which Notice shall detail the dispute, the parties involved and identify any Subcontractors that Contractor intends to withhold payment from and the amount to be withheld;

 

38


 

3.8.51 obtain and maintain the insurance set forth in Section 26.2. Contractor shall (a) cooperate with Owner so that Owner may obtain and maintain the insurance set forth in Section 26.3, including providing any information reasonably required by insurance carriers providing such insurance, and (b) comply with the requirements of the insurance policies provided by Owner pursuant to Section 26.3, including providing information necessary to substantiate any claims filed under such policies;

3.8.52 in accordance with Article 23, ensure that all agreements, guarantees, warranties, delivery schedules and performance requirements with Subcontractors comply with the requirements of this Agreement;

3.8.53 in accordance with Article 40, comply with the requirements of the Anti-Corruption Laws and Export Controls;

3.8.54 in accordance with Section 3.9, obtain recommendations for spare parts for the operation and maintenance of the Facility and, if requested by Owner, procure and deliver the Spare Parts to the Job Site;

3.8.55 as applicable comply in all respects with the requirements, prohibitions, and other obligations applicable to a general contractor under Louisiana’s Private Works Act, Louisiana Revised Statute 9:4801, et seq.;

3.8.56 as applicable after the issuance of the Notice to Proceed (or, if required by Law in connection with the performance of the scope under any Limited Notice to Proceed, the Limited Notice to Proceed) properly and timely file written notice of contract (the “Notice of Contract”), together with performance and payment bonds attached, if required, and a “no work” affidavit satisfying the requirements of Louisiana Revised Statute 9:4820.C. for registry with the recorder of mortgages of the parish in which the Work is to be performed. Preparation and filing of the notice of contract and bonds shall comply with Louisiana’s Private Works Act, La. R.S. 9:4801, et seq.;

3.8.57 as applicable upon Final Completion, file a notice of termination for registry with the recorder of mortgages for Plaquemines Parish, referencing the Notice of Contract, and satisfying the requirements of Louisiana Revised Statute 9:4822.E.;

3.8.58 as applicable as a condition precedent to final payment by Owner hereunder, supply to Company a Clear Lien and Privilege Certificate for the Facility from the recorder of mortgages for Plaquemines Parish, which certificate is dated after the expiration of the period during which Subcontractors and suppliers may file valid claims or liens pursuant to Louisiana’s Private Works Act, LA. R.S. 9:4801, et seq.; and

3.8.59 as applicable as a condition precedent to final payment by Owner hereunder, at Owner’s request, Contractor shall file, or concur with the filing of, a request for cancellation of the Notice of Contract pursuant to Louisiana Revised Statute 9:4832.A.

 

39


 

3.9

SPARE PARTS.

3.9.1 Promptly following Contractor’s issuance of a Subcontract or the execution of an Agent For Contract, Contractor shall deliver to Owner a detailed list (that shall include pricing information) of all Subcontractor, Agent For Contractor and Contractor-recommended capital spare parts, other spare parts and special tools necessary for operating and maintaining the Facility (excluding all spare parts and special tools supplied as part of the Owner Furnished Equipment and Materials), including components and systems of the Facility (collectively, “Spare Parts”), following each LNG Production System Substantial Completion Date and the Facility Substantial Completion Date. One hundred eighty (180) Days prior to LPS1 Substantial Completion Date, Owner shall specify in writing which items on the list it wishes Contractor to purchase and whether such items are requested to be delivered to the Job Site prior to LNG Production System Substantial Completion for an LNG Production System, Facility Substantial Completion or Final Completion, as applicable. For those Spare Parts Owner directs Contractor to purchase, Contractor shall purchase such Spare Parts on the best available commercially reasonable terms (including all rebates and discounts). In addition to ordering and purchasing the Spare Parts as provided above, Contractor shall receive, inspect, deliver to storage and take all other reasonable actions for the storage and maintenance of the Spare Parts until the Final Completion Date.

3.9.2 Contractor shall properly store and categorize all spare parts provided pursuant to Section 3.9.1 in order to preserve such spare parts and prevent corrosion, and shall create and maintain a computerized inventory of all such spare parts. Contractor shall submit the inventory control system to Owner for review and such inventory control system shall be approved by Owner prior to its implementation. Contractor shall cause the inventory control system to be transferred to Owner’s computer system at the Facility prior to the LPS1 LNG Production System Substantial Completion Date. Any spare parts purchased by Owner that are present at the Job Site prior to Owner’s assumption of the care, custody and control of the Facility pursuant to Section 18.1.3 and during the Warranty Period may be reasonably used by Contractor following written permission by Owner; provided, however, that Contractor shall be required to replace such spare part with an identical new replacement on an expedited basis.

3.9.3 The Parties acknowledge that Owner has directed Contractor not to supply installed spare equipment on an “n+1” basis for LPS4.

 

3.10

PROCUREMENT.

3.10.1 Within [***] Days after the date of issuance of the initial Limited Notice to Proceed, Contractor shall provide Owner with an estimated schedule of the planned air, marine and land shipments for which Contractor is responsible, identifying (a) equipment estimated to be essential to the Critical Path, (b) the equipment and values to be contained in each shipment, and (c) other specific information reasonably required by insurance underwriters (including the vessel and/or vehicle identification, the itinerary and schedule along with scheduled shipping dates from each Satellite Facility or Contractor’s, a Subcontractor’s, an Agent For Contractor’s or their supplier’s warehouse) (collectively, the “Shipping Information”). Thereafter, in order for Owner to secure insurance for each marine, air and land shipment made by Contractor, Contractor shall provide monthly updates to Owner and Owner’s designated cargo insurer of any changes to the Shipping Information. Contractor shall not permit any shipment to be made until such Notice is

 

40


 

timely given to Owner. Shipping delays incurred by Contractor or any Subcontractor or Agent For Contractor as the result of delays in securing cargo insurance to the extent due to Contractor’s failure to supply such Notice on a timely basis shall not be the basis for an Owner Caused Delay. Contractor shall ensure that all shipments of cargo by Contractor or any Subcontractors or Agent For Contractors comply with requirements related thereto of such insurance providers.

3.10.2 Each shipment manifest of Contractor and any Subcontractor or Agent For Contractor will be prepared in a format consistent with the reasonable requirements of Owner.

 

4.

COMMENCEMENT OF THE WORK.

 

4.1

NOTICE TO PROCEED.

4.1.1 Owner may issue to Contractor a Notice in the form attached hereto as Exhibit F-13 (the “Notice to Proceed ”) specifying the date for full commencement of the Work (the “Notice to Proceed Date”), which date shall not be prior to either the date that Contractor receives the Notice to Proceed or the Anticipated NTP Date and the advance payment of a mutually agreeable fixed amount that is specified in the Notice to Proceed to be due and payable upon the issuance of the Notice to Proceed. One hundred percent (100%) of such advance payment shall be credited as an offset against Reimbursable Costs, Contractor’s G&A and Contractor’s Margin owed by Owner to Contractor from and after the Notice to Proceed Date, until such advance payment is reduced to zero. Subject to any Limited Notice to Proceed, Contractor shall commence the Work only after the Notice to Proceed Date specified in the Notice to Proceed and thereafter diligently pursue the Work, assigning to it a priority that will ensure LNG Production System Substantial Completion of each LNG Production System on or before the applicable LNG Production System Substantial Completion Deadline, Facility Substantial Completion on or before the Facility Substantial Completion Deadline and Final Completion on or before the Final Completion Deadline. Contractor shall proceed with the performance of the Work in accordance with the Project Schedule; provided, however, that any failure of Contractor to pursue the Work in accordance with the Project Schedule shall not relieve Contractor of any liability hereunder. If, notwithstanding the foregoing, the Parties mutually agree in writing that Owner may issue the Notice to Proceed prior to the Anticipated NTP Date, then the Facility Substantial Completion Deadline shall be extended by the number of days equal to the number of days between the Notice to Proceed Date and the Anticipated NTP Date.

4.1.2 Prior to the issuance of the Notice to Proceed, Owner intends to obtain sufficient funds from one or more Lenders to fulfill its payment obligations under this Agreement. Owner shall not issue the Notice to Proceed until the date on which it has obtained written and binding commitments in respect of such funds.

4.1.3 On or prior to Owner’s issuance of the Notice to Proceed pursuant to this Section 4.1, Contractor shall provide the Performance and Payment Bonds to Owner as required pursuant to Article 9.

4.1.4 If Owner has not issued the Notice to Proceed pursuant to this Section 4.1 prior to [***] (or such other date as the Parties may mutually agree in writing), the Contractor may, on or within thirty (30) days following the Notice to Proceed Date, submit a claim for a Change Order to Owner for an equitable extension of the Project Schedule in accordance with Exhibit D and an adjustment to the cost overrun and cost saving values in Section 8.2 and Section 8.3, respectively, pursuant to the procedures set forth in Exhibit X.

 

41


 

4.1.5 If Owner has not issued the Notice to Proceed pursuant to this Section 4.1 prior to [***] (or such other date as the Parties may mutually agree in writing), either Party shall be permitted to terminate this Agreement by delivery of written notice thereof to the other Party.

4.1.6 If Owner issues the Notice to Proceed (i) without having issued a Limited Notice to Proceed or (ii) if the Notice to Proceed Date set forth in such Notice to Proceed is less than [***] from the date of issuance of a Limited Notice to Proceed (with approved spending as to the scope defined in Exhibit A), then each Applicable Deadline shall be extended by, in the case of clause (i), [***] and, in the case of clause (ii), [***] the number of days between the issuance of the Limited Notice to Proceed and the Notice to Proceed Date. The adjustment to the Applicable Deadlines pursuant to this Section 4.1.6 is independent from and in addition to any adjustment required under the last sentence of Section 4.1.1.

 

4.2

LIMITED NOTICES TO PROCEED.

4.2.1 Prior to the issuance of the Notice to Proceed, Owner shall have the right to issue one or more limited notices to proceed directing Contractor to commence and complete any portion of the Work specified in any such limited notice to proceed and subject to the terms of this Agreement substantially in the form attached hereto as Exhibit F-8 (each, a “Limited Notice to Proceed”), except as otherwise agreed by Owner and Contractor. All activities required to be performed thereunder shall be done in accordance with the requirements for the Work hereunder. Contractor shall not be required to commence performance of the Work described in a Limited Notice to Proceed until it has received payment of a mutually agreeable fixed amount that is specified in the Limited Notice to Proceed to be due and payable upon the issuance of the Limited Notice to Proceed. One hundred percent (100%) of such payment shall be credited as an offset against subsequent Reimbursable Costs, Contractor’s G&A and Contractor’s Margin owed by Owner to Contractor, as applicable. Upon issuance of the Notice to Proceed, all such performance of the Work under a Limited Notice to Proceed shall constitute Work done pursuant to this Agreement.

4.2.2 Owner and Contractor acknowledge that, prior to the Second Restatement Date, Owner issued Limited Notice to Proceed No. 1 (ITP) dated September 24, 2021 (“LNTP No. 1 (ITP)”) and Limited Notice to Proceed No. 2 dated November 29, 2021 (“LNTP No. 2”), in each case limited to the scope of work set forth therein, and agree to treat each of LNTP No. 1 (ITP) and LNTP No. 2 as if it was issued pursuant to this Agreement.

 

5.

PERSONNEL AND QUALIFICATIONS.

 

5.1

GENERAL.

5.1.1 Contractor represents to Owner that it, its designers and its design Subcontractors have the experience and capability necessary for the design and performance of the Work. Contractor undertakes that its personnel and design Subcontractors shall be available to attend discussions with Owner and the Independent Engineer at all times at the Job Site or other mutually agreed locations during the performance of the Contractor’s obligations hereunder.

 

42


 

5.1.2 Contractor, all Subcontractors and all personnel used by Contractor and Subcontractors in the performance of the Work shall be qualified by training, licenses or certifications, as required, and experienced to perform their assigned tasks. Contractor shall not use in the performance of the Work any personnel reasonably deemed by Owner to be incompetent, careless, unqualified to perform the work assigned to them, unsafe, creating an unsafe work environment or interfering with the completion of the Work. Notwithstanding the foregoing, Owner shall have no liability and Contractor agrees to release indemnify, defend and hold harmless each Owner Indemnitee from and against any and all Losses, of whatsoever kind or nature, which may directly or indirectly arise or result from Contractor or any Subcontractor terminating the employment of or removing from the Work any such employee who fails to meet the foregoing requirements following a request by Owner to have such employee removed from the Work.

5.1.3 Contractor shall maintain labor relations in such a manner that, so far as reasonably practicable, there is harmony among workers. Contractor and the Subcontractors shall conduct their labor relations in accordance with the recognized prevailing local area practices, applicable Law, Permits, Applicable Codes and Standards and Owner Standards.

 

5.2

KEY PERSONNEL.

The Contractor’s organizational structure for the performance of the Work is provided in Exhibit K. Prior to the commencement of the Work, the Key Personnel shall hold the positions indicated in Exhibit K. Contractor acknowledges and agrees that the continuity of Key Personnel in connection with the Work is a material requirement of this Agreement and that the replacement of any Key Personnel will be detrimental to Owner and the overall quality of the Work. The Key Personnel will be engaged full-time and exclusively in the prosecution of the Work continuously until their role is completed, unless prior release is approved or directed by Owner; provided however, Key Personnel may be removed by Contractor without Owner’s consent for (a) termination of a Key Personnel’s employment with the Contractor or its Affiliates, or (b) a Key Personnel dying, retiring, resigning, or becoming seriously ill, or a serious illness or death in the family of a Key Personnel. Revisions to the organizational structure of Key Personnel shall be subject to Owner’s prior approval, and replacement of, or additions to, such Key Personnel shall only be made with persons having qualifications equal to or better than those replaced or added to, and shall be similarly subject to Owner’s prior approval. All requests for the substitution of Key Personnel shall include a detailed explanation and reason for the request and the resumes of professional education and experience for a minimum of two (2) candidates of suitable qualifications and experience. Owner shall respond within ten (10) days of receiving the resumes with its written approval or detailed comments as to why approval is not granted. Should Owner approve of the replacement of a Key Personnel, Contractor shall allow for an overlap of a minimum of two (2) weeks during which both the Key Personnel to be replaced and the Owner-approved new Key Personnel shall work together full time. Owner may if it is concerned with the performance thereof request in writing the removal of, and Contractor shall promptly remove and replace, any Key Personnel. Contractor agrees that, notwithstanding its other business commitments, it will give the Work a priority and commit sufficient resources to the Work that will enable Contractor to perform its obligations under this Agreement.

 

43


 

6.

PRICE AND PAYMENT.

 

6.1

TARGET PRICE.

6.1.1 The “Target Price” is an amount equal to [***], the principal components of which are more fully described in Exhibit B-2, as may be adjusted from time to time pursuant to a Change Order, to be paid pursuant to Section 6.3.

6.1.2 Contractor has satisfied itself as to the correctness and sufficiency of the Target Price and represents to Owner that the Target Price is a valid estimate of the Direct Costs, the Agent For Contracts Costs and the Contractor’s G&A and Contractor’s Margin applicable thereto that will be paid to Contractor for the performance of the Reimbursable Work and the management of the Agent For Contracts. The Target Price includes the estimated costs for the Materials, labor, transportation, services and Intellectual Property rights forming part of the Reimbursable Work and, including the costs of Materials, transportation and storage of Materials and all Taxes other

than sales and use taxes, duties and tariffs for which Contractor is responsible hereunder, the cost to Contractor to provide the Performance Security, and Contractor’s estimated cost for repair or replacement of all Defects and Deficiencies and other corrective Work prior to the commencement of the Warranty Period, including as described in Exhibit B.

6.1.3 The Parties acknowledge that prior to the Notice to Proceed Date, Owner and Contractor or JV Member (as applicable) have met and will continue to meet and discuss adjustments to the components of the Work identified in Exhibit W (the “Open Cost Items”), and their associated values and schedule impacts (if any), on an open book basis, with a view to incorporating the Open Cost Items (if necessary) into the Work. The Parties will use good faith efforts to reach agreement on the final value and scope of Open Cost Items on or before April 1, 2023 and acknowledge that such agreement shall be a condition to Owner’s Financing. Following the Parties’ agreement on the Open Cost Items, Owner shall issue a Change Order to reflect the adjustments for the Open Cost Items.

 

6.2

NOT USED.

 

6.3

PAYMENT.

6.3.1 Not later than the 15th day of each Month N, Contractor shall submit to Owner for its approval a Request for Payment (simultaneously sending copies to the Independent Engineer, as Owner may direct), which shall set forth: (a) a reasonable good faith estimate of (i) the Reimbursable Work activities that will be performed during the second month (“Month N+2”) immediately following such Month N and (ii) the Direct Costs, Contractor’s G&A and Contractor’s Margin (including details of Margin Milestones anticipated to be achieved) associated with such Reimbursable Work activities (the sum of clauses (i) and (ii) being referred to herein as an “Estimated Monthly Amount”) less, in the case of the Initial Request for Payment, the amount of the advance payment described in Section 4.1.1; (b) except for the Initial Request for Payment, the amount owed to Contractor in respect of the Reimbursable Work performed during the preceding month(s), together with Contractor’s G&A and Contractor’s Margin associated with such Reimbursable Work, that has not been paid to Contractor during such preceding month(s), as

 

44


 

applicable; (c) except for the Initial Request for Payment, the amount by which the aggregate amount of Estimated Monthly Amounts paid to Contractor during the preceding month(s) exceeds the actual Direct Costs incurred by Contractor in the performance of the Reimbursable Work during the preceding month(s), calculated as of the last day of the month immediately preceding such month, and the Contractor’s G&A and Contractor’s Margin associated with such Direct Costs payable by Owner in respect of such Reimbursable Work; (d) any other amounts that may be due and owing from Owner to Contractor or from Contractor to Owner pursuant to any other provision of this Agreement; and (e) all information and documentation required by Section 6.3.3.

6.3.2 Owner shall, with respect to the Initial Request for Payment, make payment of the net amount specified in such Request for Payment within fifteen (15) Business Days of its receipt of such Request for Payment and with respect to each subsequent Request for Payment in accordance with Section 6.6.

6.3.3 Each Request for Payment submitted by Contractor pursuant to Section 6.3.1 will be accompanied by: (a) a certificate of release and waiver of liens (other than Permitted Liens) from Contractor in the form attached hereto as Exhibit F-1; (b) a Payment Status Affidavit from Contractor in the form attached hereto as Exhibit F-15; (c) certificates of release and waiver of liens (other than Permitted Liens) from each Major Subcontractor providing Materials or services described in the Request for Payment in the form attached hereto as Exhibit F-2; (d) a Payment Status Affidavit from each Major Subcontractor in the form attached hereto as Exhibit F-16; (e) a Monthly Progress Report pursuant to Section 13.3; (f) a report of Defects and Deficiencies pursuant to Section 10.2.1; (g) supporting documentation evidencing the Reimbursable Costs and Contractor’s G&A that are defined in Exhibit B; (h) the aggregate accrued amount of the Contractor’s Margin (with supporting calculations) of which payment is requested in respect of the Margin Milestone(s) that have occurred in the previous month; and (i) any other information that Owner, the Lenders or the Independent Engineer may reasonably request (provided Contractor is given a reasonable period of time (in any case, not less than ten (10) Days) to satisfy such request prior to Contractor’s submission of a Request for Payment). Contractor shall itemize Taxes (which are Reimbursable Costs) by category and cost component, including Louisiana state and local sales/use tax and any other sales/use tax that Contractor may be responsible for collecting from Owner (by state and taxing jurisdictions), import duties, and sales tax of other states (by other state). Contractor shall only include Direct Costs in a Request for Payment in accordance with the rates and other provisions set forth in Exhibit B-1 and Exhibit C.

6.3.4 Amounts (a) owed by Owner to Contractor and (b) owed by Contractor to Owner shall, to the extent not paid when due pursuant to the terms hereof, accrue interest at the Late Payment Rate from the date payment thereof was due until the date of payment thereof in full (together with all accrued interest).

6.3.5 In no event shall the payment of any amount by Owner to Contractor constitute an acceptance of any Work, and Owner’s acceptance of the Work shall not relieve Contractor of any of its obligations hereunder.

6.3.6 Notwithstanding anything to the contrary contained herein, failure by Owner to pay any amount in dispute until resolution of such dispute in accordance with this Agreement shall not alleviate, diminish, or modify in any respect Contractor’s obligations to perform hereunder.

 

45


 

6.3.7 Notwithstanding anything to the contrary contained herein, except as expressly set forth in a Limited Notice to Proceed, Contractor shall not be obligated to perform any further Work and Owner shall not be obligated to make any further payment hereunder until after the Financial Closing Date has occurred.

6.3.8 Contractor’s Margin shall only be payable as and when required pursuant to, and in the amounts specified in, the Margin Milestones.

6.3.9 All Non-Reimbursable Costs shall be borne exclusively by Contractor. Contractor shall not include any Non-Reimbursable Costs in a Request for Payment or otherwise seek reimbursement from Owner of any Non-Reimbursable Costs.

6.3.10 Owner shall have the right to audit all documentation pertaining to each Request for Payment on reasonable prior notice to Contractor and during normal business hours in order to confirm the accuracy and completeness of such Request for Payment.

 

6.4

ENCUMBRANCES.

6.4.1 Contractor covenants and agrees that, with the sole exceptions of (a) an arbitral or Government Authority’s decision in Contractor’s favor and (b) Permitted Liens, no mechanics’ liens, similar liens or any encumbrances whatsoever shall be filed or maintained by Contractor, any Subcontractor, any Agent For Contractor, or worker or other Person acting, directly or indirectly, through or under Contractor or any Subcontractor or Agent For Contractor, against the Job Site, the Facility (or any portion thereof), any Materials or Owner Furnished Equipment and Materials, any land or improvements pertinent thereto, for or on account of any Work done or to be done or Materials furnished or to be furnished hereunder (the foregoing types of liens, regardless of who files them, collectively, the “Indemnified Liens”). Any lien or encumbrance filed by Contractor shall be limited in scope to secure payment by Owner of the amount at issue in any applicable dispute resolution proceeding. Upon Owner’s payment of such amount, Contractor shall immediately, and in any event within seven (7) Days of such payment, effect release (and certify thereto) of any such lien or encumbrance. For the avoidance of doubt, if a dispute resolution proceeding is brought within the applicable statute of limitations, but the outcome of such proceeding is not determined until after the statute of limitations has expired, the Parties agree to waive the statute of limitations in order to effect the outcome of such dispute resolution proceeding.

6.4.2 If Contractor fails to satisfy the obligation set forth in Section 6.4.1 within thirty (30) days, Contractor agrees, to the fullest extent permitted by Law, to indemnify and hold harmless each of the Owner Indemnitees and the Owner’s title insurers against any and all Losses associated with any Indemnified Lien or any lien on an asset of Owner, and Owner shall have the right to (a) consider the amount of the lien or encumbrance as presumptively correct, (b) withhold from any payment to Contractor then due, or thereafter to become due (including the Final Request For Payment), an amount sufficient to completely indemnify Owner Indemnitees against such lien or encumbrance, (c) pay the amount of such lien or encumbrance and pursue recovery actions against Contractor and (d) retain out of the amount withheld an amount sufficient to compensate Owner for its expenses (including actual attorney’s fees) in the matter.

 

46


 

6.4.3 Contractor hereby subordinates any mechanics’ and materialmen’s liens or other claims or encumbrances that may be brought by Contractor against any or all of the Work, the Facility, or the Job Site to any liens granted in favor of the Lenders, whether such lien in favor of the Lenders is created, attached or perfected prior to or after any such liens, claims or encumbrances, and shall use commercially reasonable efforts to require its Subcontractors to similarly subordinate their lien, claim and encumbrance rights. Contractor agrees to comply with reasonable requests of Owner for supporting documentation required by the Lenders in connection with such subordination, including any necessary lien subordination and other agreements and the filing of necessary documentation to effectuate such subordination. Nothing in this Section 6.4.3 shall be construed as a limitation on or waiver by Contractor of any of its rights under applicable Law to file a lien or claim or otherwise encumber the Facility as security for any undisputed payments owed to it by Owner hereunder which are past due; provided that such lien, claim or encumbrance shall be subordinate to any liens granted in favor of the Lenders.

 

6.5

DEFICIENT REQUESTS FOR PAYMENT.

Should Owner and the Lenders believe any Request for Payment is non-conforming (by being incomplete or inaccurate or by not otherwise satisfying the requirements for a Request for Payment hereunder), Owner shall have the right, in its sole discretion, to (a) request additional information with respect to such non-conforming Request for Payment or (b) reject the non-conforming portion of a Request for Payment, but pay the undisputed portion in accordance with this Agreement. It is understood and agreed by the Parties that any Request for Payment which is non-conforming, to the extent of such non-conformance, shall not constitute a valid and proper Request for Payment, and Owner shall not be obligated to make payment of any disputed amounts related to such non-conformance until Contractor revises the Request for Payment or submits a Request for Payment in proper form.

 

6.6

OWNER PAYMENT OBLIGATIONS.

Owner shall review each Request for Payment and may make such exceptions in accordance with the terms of this Agreement. Not later than forty-five (45) Days after its receipt of a Request for Payment and supporting documentation in the manner, with such detail and at the time herein required, Owner shall make payment to Contractor in the amount required, less (i) any disputed portion of such Request for Payment, (ii) any undisputed amounts payable by Contractor to Owner hereunder from the immediately preceding billing period and (iii) any other Owner withholding rights explicitly set forth herein. Owner shall make payment of the net amount specified in each Request for Payment submitted in accordance with Section 6.3, less (i) any disputed portion of such Request for Payment, (ii) any undisputed amounts payable by Contractor to Owner hereunder from the immediately preceding billing period and (iii) any other Owner withholding rights explicitly set forth herein, not later than the last Business Day of the month immediately following the month in which such Request for Payment was received by Owner; provided, however, that if Contractor submits such Request for Payment to Owner after the 15th day of the relevant month, the time period within which Owner shall be obligated to make payment hereunder shall be extended by such number of days following such 15th day for which such Request for Payment was not submitted. See Exhibit B-4 for an example of such payment procedures.

 

47


 

6.7

FINAL PAYMENT.

Within thirty (30) days of the Final Completion Date, Contractor shall submit a final Monthly Progress Report and a final request for payment which shall set forth all amounts due and remaining unpaid to it (the “Final Request for Payment”), and upon approval thereof by Owner, Owner shall pay to Contractor the amount due under such Final Request for Payment. Together with the submission of the Final Request for Payment to Owner, Contractor shall: (a) furnish Owner a Clear Lien and Privilege Certificate pursuant to Section 3.8.58; (b) deliver evidence satisfactory to Owner that Contractor has filed a request for cancellation of the Notice of Contract pursuant to Section 3.8.59 and (c) deliver evidence satisfactory to Owner, including a Payment Status Affidavit from Contractor and all Major Subcontractors in the form of Exhibit F-15 and Exhibit F-16, respectively, and a release and waiver of liens from Contractor and all Major Subcontractors in the form of Exhibit F-3 and Exhibit F-4, respectively, that all claims, liens, security interests or encumbrances in the nature of mechanics’, labor or materialmen’s liens or otherwise, arising out of or in connection with the Facility, Job Site or the performance by Contractor, or any Major Subcontractor, of the Work, have been satisfied or discharged.

 

6.8

OWNER’S RIGHT TO WITHHOLD PAYMENT.

6.8.1 Notwithstanding anything to the contrary contained herein, upon the occurrence and continuance of any of the following events, Owner, upon Notice to Contractor, may withhold or retain such portion (including all) of any payment due to Contractor under this Agreement as reasonably necessary to ensure the performance of the Work or to protect fully Owner’s rights hereunder:

(a) Contractor is in default under Section 31.1 or has otherwise failed to perform any of its material obligations hereunder, but excluding (i) defaults for which the payment of liquidated damages is the sole and exclusive remedy as provided in Article 22, and (ii) costs attributable to any such default that are otherwise Direct Costs as provided in Exhibit B-1;

(b) there exists any outstanding and unpaid payment obligation owing by Contractor;

(c) provided that Contractor is then obligated to indemnify Owner for liens, (i) Contractor is not able to indemnify Owner to Owner’s satisfaction against any such lien that shall be registered against the Job Site, Facility (or any portion thereof), any Materials, any land or improvements pertinent thereto and such lien shall remain undischarged or (ii) Contractor, Owner or the Lenders shall have received any claims for liens arising in connection with this Agreement which have not been withdrawn, all arising as a result of any acts or omission of Contractor or any Subcontractors or Agent For Contractors;

(d) Owner is required in accordance with applicable Laws to withhold Taxes payable by Contractor in respect of the Work;

(e) there is an assessment of any fines or penalties against Owner as a result of Contractor’s failure to comply with applicable Law, Permits or Applicable Codes and Standards;

 

48


 

(f) Contractor has failed to make payments to Subcontractors as required under their respective Subcontracts, excluding the right of Contractor to withhold payments to Subcontractors as provided under the terms of the applicable Subcontract; or

(g) Owner has incurred any other Non-Reimbursable Costs or liabilities for which Contractor is responsible hereunder.

6.8.2 Owner’s right to withhold amounts pursuant to this Section 6.8 shall not be deemed to in any way reduce Owner’s rights to withhold amounts due to Contractor under any other Section hereof. If Owner withholds amounts pursuant to this Section 6.8, Owner shall promptly inform Contractor of the reason therefor and once Contractor has corrected the reasons for the withholding, Owner shall pay the said withheld amount with the next Request for Payment submitted by Contractor. Notwithstanding anything to the contrary contained herein, Contractor shall not have any rights of termination or suspension as a result of Owner’s exercise of its rights under this Section 6.8.

 

6.9

RELEASE OF LIABILITY.

Acceptance by Contractor of payment pursuant to a Final Request for Payment shall constitute a satisfaction and release by Contractor and each of its Subcontractors in favor of Owner, Owner’s Representative, the Lenders, the Independent Engineer and all Affiliates, officers, directors, employees and agents thereof from all claims and liability hereunder with respect to the Work, or for any act or omission of Owner or of any of the above-listed Persons relating to or affecting this Agreement, except for (a) claims which are the subject of a Dispute filed by either Owner or Contractor prior to the date of such payment pursuant to Article 36, (b) Owner’s indemnity obligations hereunder, (c) any payment that may become due to Contractor under the last sentence of Section 6.7, or (d) any other provision hereof that is expressly intended to survive. Subject to acceptance of the Facility by Owner upon the Facility Substantial Completion Date, no payment shall: (i) be deemed a representation that Owner has inspected the Materials or the Work, (ii) constitute or be deemed an acceptance, in whole or in part, of any portion of the Work or

(iii)operate

to release Contractor from any obligations or liabilities hereunder.

 

7.

NET LNG SALES PROCEEDS.

 

7.1

PRE-COMMERCIAL PRODUCTION.

[***]

 

7.2

NO GUARANTY OF NET LNG SALES PROCEEDS.

[***]

 

49


 

8.

COST OVERRUN; COST SAVINGS.

 

8.1

TOTAL COSTS.

8.1.1 Contractor acknowledges and understands that Owner has structured its Financing on the basis of the Target Price. Accordingly, Contractor agrees as a consequence that the Contractor’s Margin shall be subject to adjustment under the circumstances described in this Article 8, without impacting Owner’s obligation to reimburse Contractor for Direct Costs incurred by it in accordance with this Agreement.

8.1.2 For the purposes of this Agreement, “Total Costs” means, as of any date, an amount equal to the sum, as calculated by Owner pursuant to Section 8.2.3, of: (a) the Reimbursable Costs, Contractor’s G&A and Contractor’s Margin duly paid to Contractor by Owner pursuant to Section 6.3; (b) the Agent For Contracts Costs; (c) any costs incurred by Owner to perform portions of the Work or any other Contractor obligation that should have been performed by Contractor under this Agreement that are in excess of the amount that Owner would have paid to Contractor to perform such portions of the Work; and (d) any other cost expressed to be included in the calculation of Total Costs hereunder; provided that the Total Costs shall not include the Total Cost Exclusions. For the avoidance of doubt, the calculation of the Total Costs as of the Final Completion Date shall include all such amounts owing, but not yet paid, to Contractor with respect to the Work performed through and including the Final Completion Date, including amounts set forth in the Final Request for Payment.

 

8.2

COST OVERRUN.

8.2.1 In the event that at any time a Cost Overrun exists that is greater than [***], Owner shall be permitted by written notice to Contractor to reduce the Contractor’s Margin for all purposes hereunder as follows:

(a) if the Cost Overrun is greater than [***], but less than or equal to [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***];

(b) if the Cost Overrun is greater than [***], but less than or equal to [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***];

 

50


 

(c) if the Cost Overrun is greater than [***], but less than or equal to [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***]; and

(d) if the Cost Overrun is greater than [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***].

8.2.2 Owner shall be permitted to reduce the Contractor’s Margin pursuant to Section 8.2.1 more than once if following Owner’s first delivery of a notice pursuant to Section 8.2.1 a Cost Overrun increases to exceed the next then applicable threshold set forth therein. Each reduction of Contractor’s Margin effected pursuant to Section 8.2.1 shall be applied both retroactively and prospectively, and all payments by Owner of Contractor’s Margin made prior to such reduction shall be retroactively adjusted to be equal to an amount calculated using the reduced Contractor’s Margin. In such event, without prejudice to Section 41.7, Owner may deduct from any amounts owed to Contractor hereunder an amount equal to the positive difference between the amount of the Contractor’s Margin previously paid to Contractor pursuant to Section 6.3 calculated using the previously applicable Contractor’s Margin and the amount of the Contractor’s Margin previously paid to Contractor as recalculated using the reduced Contractor’s Margin. Each notice delivered by Owner pursuant to Section 8.2.1 shall include Owner’s supporting calculations of the amount of the relevant Cost Overrun and, if applicable, the amount of such positive difference to be deducted from amounts owed to Contractor.

8.2.3 [***]

8.2.4 The Parties acknowledge and agree that (a) the Dollar values in Sections 8.2.1 and 8.2.3 are subject to adjustment pursuant to Section 4.1.4 and (b) the remedies set forth in this Section 8.2 are reasonable and appropriate measures of the damages for the circumstances described herein and do not represent a penalty.

 

51


 

8.2.5 The Parties acknowledge that the Dollar values in Section 8.2.1 reflect necessary adjustments relating to the cost of Performance and Payment Bonds, aggregate and the aboveground fuel pipe for the Phase 1 Work (excluding for this purpose LPS4) which were not included within the proposal set forth in Exhibit Z.

 

8.3

COST SAVINGS.

8.3.1 Within thirty (30) days following the Final Completion Date, Owner shall calculate and deliver to Contractor written notice of the Cost Savings, if any, such notice to include Owner’s supporting calculations of the amount of the Cost Savings. The Cost Savings shall be calculated as of the Final Completion Date. If there is a Cost Savings that is greater than [***], Owner shall make payment of the following amount to Contractor within fifteen (15) days of Owner’s delivery of written notice to Contractor:

(a) if the Cost Savings is greater than [***], but less than or equal to [***], an amount equal to [***] of the amount of the Cost Savings;

(b) if the Cost Savings is greater than [***], but less than or equal to [***], an amount equal to [***] of the amount of the Cost Savings;

(c) if the Cost Savings is greater than [***], but less than or equal to [***], an amount equal to [***] of the amount of the Cost Savings; and

(d) if the Cost Savings is greater than [***], an amount equal to [***] of the amount of the Cost Savings.

8.3.2 The Parties acknowledge and agree that the Dollar values in Section 8.3.1 are subject to adjustment pursuant to Section 4.1.4.

 

9.

PERFORMANCE SECURITY.

 

9.1

TYPES OF PERFORMANCE SECURITY.

To secure Contractor’s performance of its obligations hereunder, Contractor acknowledges and agrees that Owner shall have the right to hold (a) the Performance and Payment Bonds and (b) the Contractor Guarantees.

 

52


 

9.2

PERFORMANCE AND PAYMENT BONDS.

9.2.1 On or prior to the Notice to Proceed Date, Contractor shall deliver to Owner a performance bond (in the form of a bank letter of credit that is in form and substance satisfactory to Owner, such form to be included as Exhibit F-9A) and a payment bond (in the form of an insurance surety bond as provided in Exhibit F-9B) issued for the benefit of Owner (the “Performance and Payment Bonds”), in each case issued by a Qualified Surety.

9.2.2 The Performance Bond shall constitute security for all of Contractor’s payment and performance obligations hereunder. The Performance Bond shall have a face amount equal to [***] of the initial Target Price. In the event the Target Price is increased by one or more Change Orders or otherwise in an aggregate amount equal to or greater than [***] in accordance with the terms of this Agreement prior to the Facility Substantial Completion Date, Contractor shall increase the amount of the Performance Bond to reflect the corresponding increase in the Target Price by [***] of such increase, within [***] Days of such increase in the Target Price. Upon Facility Substantial Completion, the face amount of the Performance Bond shall be reduced to an amount equal to [***] of the then current Target Price. The Performance Bond will be held by Owner until the expiration of the Warranty Period.

9.2.3 The Payment Bond shall constitute security for the payments made by Owner to Contractor on or after the Notice to Proceed Date. The Payment Bond shall have a face amount equal to a variable percentage of the initial Target Price, as follows: (i) as of the Notice to Proceed Date, the face amount of the Payment Bond shall be equal to [***] of the initial Target Price; (ii) on the date that is [***] days following the Notice to Proceed Date, the face amount of the Payment Bond shall be increased to be equal to [***] of the initial Target Price; (iii) on the LPS1 Substantial Completion Date, the face amount of the Payment Bond shall be decreased to be equal to [***] of the initial Target Price; and (iv) on the LPS4 Substantial Completion Date, the face amount of the Payment Bond shall be decreased to be equal to [***] of the initial Target Price. The Payment Bond will be held by Owner until the Facility Substantial Completion Date.

9.2.4 In the event amounts are due under this Agreement from Contractor to Owner (including Schedule Delay Liquidated Damages), and such amounts are not paid by Contractor when due, Owner shall have the right, commencing [***] Business Days following Owner’s delivery of written notice thereof to Contractor, to draw amounts under the Performance Security equal to the amount owing by Contractor.

9.2.5 If at any time the surety that has issued the Performance and Payment Bonds is no longer a Qualified Surety, then Contractor shall replace such Performance and Payment Bonds with a replacement instrument complying with the terms hereof from a Qualified Surety within [***] Business Days from receiving notice from Owner.

 

9.3

CONTRACTOR GUARANTEES.

9.3.1 Owner acknowledges receipt of the Contractor Guarantees. Contractor shall cause each of the Contractor Guarantees to remain in full force and effect until the expiration of the Warranty Period. Contractor acknowledges that Owner shall have the right, in its sole discretion, to issue demands for payment under either or both of the Contractor Guarantees.

 

53


 

9.3.2 As soon as available, but in any event within [***] Days after the end of the first three fiscal quarters of each Contractor Guarantor, Contractor shall deliver to Owner the unaudited and consolidated balance sheet of such Contractor Guarantor, as of the end of such quarter, the related consolidated statements of income, cash flows, and retained earnings and stockholders’ equity for such quarter, all of which shall be certified by the chief financial officer or equivalent officer of such Contractor Guarantor subject to normal year-end audit adjustments. As soon as available, but in any event no later than [***] Days after the end of each fiscal year of each Contractor Guarantor, Contractor or such Contractor Guarantor shall deliver to Owner a copy of the audited consolidated balance sheets at the end of each such year as well as the related consolidated statements of income, retained earnings, and cash flows for such year. All financial statements delivered pursuant to this Section 9.3 shall be complete and correct in all material respects and shall be prepared in accordance with generally accepted accounting principles applied consistently throughout the periods reflected therein. If a Contractor Guarantor makes the foregoing financial statements publicly available on its website or through filings pursuant to applicable securities laws, then the requirements of this Section 9.3 shall be deemed met by such Contractor Guarantor making such financial statements publicly available in accordance with the requirements of applicable securities laws or, otherwise, in accordance with its customary practice.

 

10.

QUALITY CONTROL AND INSPECTION.

 

10.1

QUALITY MANAGEMENT PLAN.

Within thirty (30) Days after the earlier of the Limited Notice to Proceed or Notice to Proceed, and prior to commencing any aspect of the Work, Contractor shall have submitted for Owner’s review and approval, and Owner shall have approved, as being in accordance with Owner Standards, a formal program for inspecting and testing all aspects of the Work (the “Quality Management Plan”). Owner shall have a period of thirty (30) Days following submittal to it of the Quality Management Plan to approve or comment upon the Quality Management Plan. If Owner approves the Quality Management Plan, or Owner does not approve or provide comments on the Quality Management Plan within such thirty (30) Day period, then Contractor may proceed to implement such Quality Management Plan; provided, however, that Owner may at any time require Contractor to amend the Quality Management Plan if it is not in accordance with the requirements of this Agreement. The individual(s) responsible for implementing the Quality Management Plan shall be identified by Contractor to Owner.

 

10.2

DEFECTS AND DEFICIENCIES.

10.2.1 Contractor shall perform, or cause to be performed, quality control and inspection activities related to the Work as required by the Contractor’s Quality Management Plan, this Agreement and Owner Standards. Prior to entering any purchase orders for Materials or any Subcontracts, Contractor shall provide Owner the quality control and inspection program for such Subcontractor, and Contractor shall (i) ensure that each such program is substantially the same as the approved Quality Management Plan, and (ii) require each such Subcontractor to provide

 

54


 

periodic reports and maintain accurate and ongoing records showing compliance with each such quality control and inspection program. The Quality Management Plan must be adequate to meet the quality control and inspection needs of the Work, and Contractor may not rely upon Owner or any other Person or Government Authority to provide such services. Contractor shall inspect and test the Work, including all design, engineering, installation, Materials, tools and supplies performed or provided. All Defects or Deficiencies identified by such inspection or testing shall be included in the Monthly Progress Report submitted to Owner with the Contractor’s Request for Payment. The Monthly Progress Report shall describe in detail (a) all such Defects or Deficiencies identified, including a failure analysis of the problem, (b) a description of the solutions identified for each such Defect and Deficiency, (c) all Work that was re-performed or corrected and any related services rendered during the immediately preceding month and (d) all such Defects or Deficiencies not then corrected or re-performed. Contractor shall identify a solution for each such Defect and Deficiency as soon as possible, but in any event not later than seven (7) days after the date that such Defect and Deficiency is identified, and, in the case of known defects or deficiencies in Owner Furnished Equipment and Materials, notify and request a solution from Owner or Owner Contractors.

10.2.2 Contractor shall correct, or cause to be corrected, all Defects and Deficiencies as soon as practicable under the circumstances, and shall correct, or cause to be corrected, (a) any Defects or Deficiencies identified during the design process prior to the date that the procurement process begins, (b) any Defects or Deficiencies identified during the procurement process prior to the date that the shipping of Materials and equipment begins, (c) any Defects or Deficiencies identified during the performance of the Work prior to the start of the Demonstration Tests, (d) any Defects identified during the Demonstration Tests prior to the start of the Performance Tests (excluding Punch List Items) and (e) any Defects or Deficiencies identified during the Performance Tests prior to re-running the Performance Tests (excluding Punch List Items); provided that with respect to clauses (a) through (e) above, Contractor shall have the right, upon prior written notice to Owner, to re-sequence the Work (including not correcting the Defects in the order required by this Section 10.2.2) as necessary to correct such Defects or Deficiencies as efficiently and expeditiously as possible.

 

10.3

INSPECTION RIGHTS.

Owner and the Owner Designees shall have the right to inspect in accordance with Owner Standards all Work performed in accordance with this Agreement and any item of Materials, service or workmanship to be provided in accordance with this Agreement as and to the extent described in Exhibit A or referred to elsewhere herein, and Contractor shall arrange such inspection, at the request of Owner, at any location that Work is performed or where Materials are fabricated or stored. With respect to tests which Contractor is required to perform hereunder pursuant to Exhibit A or Exhibit R, whether the tests take place at Contractor’s factory, or at the factory of a Subcontractor or Agent For Contractor, or the Job Site, Contractor shall supply all necessary labor, materials, equipment, apparatuses, instruments and competent test personnel who shall be able to take complete charge of the tests, and shall be authorized to represent and make decisions for the proper carrying out of the tests; provided, however, that with respect to any test set forth in Exhibit A or Exhibit R which Owner or the Owner Designees are entitled to witness, Contractor shall not be required to re-perform such test by virtue of Owner’s or the Owner Designees’ failure to observe same if Owner shall have been given at least fifteen (15) Days’ notice

 

55


 

thereof (except for routine in process inspections). Owner shall at any time have the right to reject, or to direct Contractor to reject, any such portion of the Work, including any design, engineering, Materials, installation, tools or supplies, which in Owner’s reasonable judgment do not conform to the provisions hereof, including the requirements set forth in Exhibit A and the Drawings and Specifications, or which contain Defects or Deficiencies. Upon such rejection, Contractor shall as soon as practicable under the circumstances, but in no case later than the commencement of the Performance Tests, remedy any such condition identified by Owner as giving rise to such rejection. In the case of discovered defects or deficiencies in Owner Furnished Equipment or Material, Contractor shall promptly notify Owner. Copies of all test certificates, performance curves and data sheets required by Owner shall be supplied by Contractor to Owner’s Representative in reproducible form. Sufficient information is to be given on all test certificates, performance curves and data sheets to enable the Materials to which they refer to be identified.

 

10.4

THIRD PARTY INSPECTION.

Contractor understands that the Owner Designees or the Lenders, and certain Government Authorities have or shall have the right, from time to time, to observe and inspect the Work and the Facility and to observe all tests of the Work and the Facility. Contractor shall allow such third-party inspectors access to the Work and the Facility and to the Contractor’s technical and design records pertaining thereto, so long as either Owner’s Representative is present or Contractor has obtained the prior written approval of Owner. Owner agrees to protect as confidential anything designated by Contractor as such, whether by notation thereon or separate Notice; provided that in no event shall Owner be liable to Contractor for the failure of any party (other than Owner) to comply with the confidentiality requirements of Contractor.

 

10.5

EFFECT OF WAIVER OF INSPECTION RIGHTS.

In the event that Owner or the Owner Designees shall waive or fail to exercise their right to test and inspect as herein provided, such waiver or failure shall in no way relieve Contractor of its obligations to perform the Work, or any part of it, in accordance with this Agreement, nor shall such waiver or failure prejudice or affect the rights of Owner or the Owner Designees set forth herein; nor shall any test or inspection by Owner, any Lenders or the Owner Designees or any failure to test or inspect be construed as an approval or acceptance of the Work or any part thereof. However, if any test or inspection is otherwise successful, the failure of any or all of Owner or the Owner Designees to attend such test or inspection shall not alter the successful nature of the test or inspection; provided, however, that Contractor shall promptly provide to Owner detailed information of the test or inspection, including the information specified in Section 10.3.

 

11.

HEALTH, SAFETY, SECURITY AND ENVIRONMENT

 

11.1

COMPLIANCE.

Contractor shall be a “prime contractor” for all purposes under the Occupational Safety and Health Act of 1970 and shall take all actions necessary or advisable to ensure compliance with OSHA regulations and the health and safety of all persons at the Job Site, or portion thereof, until the earlier of (a) Owner’s issuance of written notice that Owner will assume the role of prime contractor for the Job Site, or such area or areas within the Job Site as specified in such notice, and (b) the termination of this Agreement.

 

56


 

11.2

HSSE PROGRAM.

11.2.1 Within sixty (60) Days after the date of issuance of Limited Notice to Proceed contemplated by Section 4.2.1, and prior to commencing any aspect of the Work, Contractor shall have submitted for Owner’s review and approval, and Owner shall have approved, as being in accordance with Owner Standards and Exhibit U, a formal health, safety, security and environment program (the “HSSE Program”). Owner shall have a period of thirty (30) Days following submittal to it of the HSSE Program to approve or comment upon the HSSE Program. If Owner approves the HSSE Program, or Owner does not approve or provide comments on the HSSE Program within such thirty (30) Day period, then Contractor may proceed to implement such HSSE Program; provided, however, that Owner may at any time require Contractor to amend the HSSE Program if it is not in accordance with the requirements of this Agreement, including those set forth in Exhibit U. The individual(s) responsible for implementing the HSSE Program shall be identified by Contractor to Owner. Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work in accordance with applicable Law, the Contractor’s safety procedures and Owner Standards.

11.2.2 Contractor shall provide sufficient supervision for health, safety, security and environmental protection (“HSSE”) and take all precautions necessary to provide all protection to prevent damage, injury or loss to (a) all employees engaged in connection with the Work and all other Persons who may be affected thereby, (b) all the Work and all Materials to be incorporated therein, whether in storage on or off the Job Site, under the care, custody or control of Contractor or any Subcontractors or Agent For Contractors, (c) other property at the Job Site or adjacent thereto or the access route to the Job Site, including trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction or (d) the environment (except as otherwise permitted under any Permit); provided that Contractor’s obligations in regard to (b), (c) and (d) shall be to comply with applicable Law, Permits, Owner Standards and the HSSE Program.

 

11.3

SAFEGUARDS.

Contractor shall erect and maintain, as required by existing conditions and progress of the Work, all HSSE-related safeguards, including physical barriers, fences and railings. Contractor shall post danger signs and other warnings against hazards, promulgate safety regulations and notify owners and users of adjacent utilities of any dangerous or hazardous conditions. In accordance with Laws, Permits, Applicable Codes and Standards, and Owner Standards, Contractor shall exercise the utmost care in the use and handling of explosives or other Hazardous Substances or equipment and only competent, trained and experienced employees of Contractor or of any Subcontractor or Agent For Contractor shall be permitted to handle such explosives or other Hazardous Substances or equipment. All warning signs and notices shall be in English, Spanish and such other language as appropriate so that the safety communications will be understood by all personnel.

 

57


 

11.4

HSSE INCIDENTS.

Contractor shall have the following HSSE incident and near miss reporting obligations:

11.4.1 Contractor shall report in writing to Owner (and, to the extent required by any applicable Law, Applicable Codes and Standards or applicable Permit, the appropriate Government Authority) details of any HSSE-related incident that occurs on or in the vicinity of the Job Site as soon as possible after its occurrence, but in any event no later than twenty-four (24) hours after such HSSE-related incident occurs. In the case of any fatality or Severe Injury, Contractor shall immediately (a) notify Owner (and, to the extent required by any applicable Law, Applicable Codes and Standards or Permits, the appropriate Government Authority), (b) stop all Work on or in the vicinity of the Job Site, (c) and schedule a meeting as soon as practical (but no later than twenty-four (24) hours after the occurrence of such fatality or Severe Injury) with Owner to review the incident and, if necessary and/or required by Owner, revise the Contractor’s HSSE precautions and programs. Following any meetings with Owner pursuant to this Section 11.4.1, Contractor shall implement all reasonable revisions to the Contractor’s safety precautions and programs as required by Owner, and upon Notice from Owner, Contractor shall recommence the performance of the Work. Contractor shall initiate incident investigations as soon as practical (but no later than forty-eight (48) hours after the occurrence of such HSSE-related incident). Owner shall be invited to participate in all investigations, and may elect to be an active participant in any investigation and reserves the right to perform a parallel investigation. Contractor shall promptly send Owner copies of all citations issued by a Government Authority against Contractor resulting from or relating to an incident while performing the Work. Contractor shall report any HSSE-related incident and near misses at weekly HSSE meetings for review and discussion. Any delays in, or additional costs incurred in connection with, the Work resulting from the Contractor’s compliance with this Section 11.4.1 shall not form the basis for a Change Order.

11.4.2 In the event of any emergency situation that endangers or could endanger life, property or the environment, Contractor shall take such action as may be reasonable and necessary to prevent, avoid or mitigate injury, damage or loss and shall, as soon as possible, report any such incidents, including the Contractor’s response and actions with respect thereto, to Owner.

11.4.3 Whenever Owner shall, in its sole discretion, determine that such an emergency situation exists, or is imminent, with respect to any part or all of the Work or other activities on the Job Site, Owner shall have the right to occupy and control the Job Site and, should Owner deem it necessary, to modify any aspect of the Work related to such emergency situation including stopping or altering the Work.

 

12.

CHANGES IN THE WORK.

 

12.1

GENERAL.

12.1.1 Owner may at any time order changes to the Work. Contractor may propose changes to the Work for Owner’s consideration; provided that Owner shall not be obligated to approve any such change. Contractor shall be entitled to receive a Change Order in accordance with the provisions of Section 12.1.2 with respect to: (a) Force Majeure Events; (b) Owner Caused Delays; (c) Owner-directed or approved changes; (d) any failure by an Owner Contractor to

 

58


 

perform its material obligations under the relevant Owner Contract that demonstrably and adversely affects Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule; (e) any error, inaccuracy or omission in or change by Owner to the Relied Upon Information that demonstrably and adversely affects Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule; (f) as provided elsewhere in this Agreement including in Sections 4.1.4, 12.4 and 16.3.2; (g) Pre-Existing Hazardous Substances which demonstrably and adversely impact Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule (except to the extent any additional costs or delay is the result of Contractor’s, its Subcontractors’ or Agent For Contractor’s Grossly Negligent act or omission or Willful Misconduct in the handling, storage or transportation of any Pre-Existing Hazardous Substance after discovery by Contractor, a Subcontractor or Agent For Contractor); (h) suspensions in the Work in accordance with Section 17.1.1 or Section 17.1.3 , (i) a Carrollton Gage Delay; and (j) any soils improvement cement reagent adjustment; provided that, with respect BH Testing Delay, the Change Order which shall be limited to a day-for-day extension of the applicable LNG Production System Substantial Completion Date or the Facility Substantial Completion Date, as the case may be, equal to the number of days of such BH Testing Delay.

12.1.2 Contractor shall be entitled to receive only one Change Order with respect to the same act or event and shall not be entitled to aggregate the cumulative impact of such act or event or two or more acts or events. Unless a particular activity is demonstrated to adversely impact an LNG Production System Substantial Completion Deadline or the Facility Substantial Completion Deadline, no adjustment to such LNG Production System Substantial Completion Deadline or Facility Substantial Completion Deadline, as applicable, shall be made, and any adjustments to the Project Schedule made in connection with a Change Order shall take into account any available float for such activity that is affected by a Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable.

12.1.3 Except for Owner-directed changes under Section 12.3, all changes in the Work shall be authorized by a written Change Order executed by Owner and Contractor. Any such Change Order shall be accompanied by additional and/or revised Drawings and Specifications, as reasonably necessary, and shall be priced as provided in Section 12.2. All such changes shall be performed under and governed by the provisions hereof and the relevant Change Order. Contractor acknowledges and agrees that the Independent Engineer is not an agent of Owner and is not authorized to execute Change Orders on behalf of Owner.

12.1.4 Contractor agrees that any Change Order shall constitute the final and complete compensation and satisfaction for all costs and schedule effects related to (a) the implementation of the stated changes, (b) the cumulative impact of effects resulting from the stated changes on all prior Work and changes in the Work to be performed as scheduled and (c) any costs associated with expediting the Work to mitigate the effect of any change or delay which costs shall be included in the Change Order. Contractor expressly waives any claims for additional compensation, damages or time extension in connection with the stated changes; provided, however, that if a Dispute exists with respect to any Change Order (whether proposed by Contractor or Owner), such Dispute shall be resolved pursuant to the dispute resolution provisions set forth in Article 36.

 

59


 

12.1.5 No Change Order shall be issued in connection with any Defects or Deficiencies on the part of Contractor or any Subcontractor or Agent For Contractor in the performance of the Work hereunder. No Change Order shall be issued in connection with the performance or completion of the Pre-Approved Site Work.

12.1.6 No Change Order request by Contractor shall be permitted after the Final Request for Payment is submitted. The Parties shall not be bound to any changes to the Work or this Agreement unless expressly set forth in a Change Order that has been signed by both Parties (or solely by Owner under Section 12.3.1) or determined in accordance with the dispute resolution procedures set forth in Article 36.

12.1.7 Contractor shall not comply with any oral changes in the Work received from or on behalf of Owner.

12.1.8 Except as specifically set forth in a Change Order, no Change Order shall modify or affect: (a) the Work or the requirements set forth herein; (b) the Target Price; (c) the Project Schedule; (d) the Critical Path; (e) any Applicable Deadline, (f) the Demonstration Tests or the Performance Tests; or (g) any other right, liability or obligation of Contractor hereunder.

 

12.2

CHANGE ORDER PROCESS.

12.2.1 Contractor shall provide Notice to Owner as soon as practicable, but no later than five (5) Business Days, after the time when Contractor knows of the impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that will impact the Work. Failure to provide such Notice within ten (10) Business Days after the time when Contractor knows of the impact of any Force Majeure Event shall be deemed to be a waiver of the Contractor’s right to receive a Change Order with respect thereto. Such Notice shall, to the extent practicable, specify the estimated impact on the Target Price and/or the Project Schedule, as applicable, the impact upon the various portions of the Work occasioned by reason of such Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, and shall substantiate the foregoing to the satisfaction of Owner. In the event that Contractor does not know or is unable to specify with reasonable certainty the impact upon the Work at the time such Notice is to be delivered, Contractor shall instead provide Owner with a notice of a potential or anticipated impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that could impact the Work, and shall thereafter provide Owner (and, if requested by Owner, the Independent Engineer) with periodic supplemental Notices during the period that the Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable, continues, detailing any developments, progress or other relevant information of which Contractor is aware. To the extent Owner (in consultation with the Independent Engineer with respect to a Material Change) agrees with the Contractor’s determination of a Force Majeure Event or Owner Caused Delay or any other basis for a Change Order, as applicable, and the effects thereof, Owner shall notify Contractor of Owner’s acceptance. In the event Owner (in consultation with the Independent Engineer with respect to a Material Change) does not accept the Contractor’s findings, Owner or Contractor shall be permitted to dispute such Change Order in accordance with Article 36, and Contractor shall be paid for any Work performed in respect of such disputed Change Order as provided in Section 12.2.5.

 

60


 

12.2.2 As soon as practicable, and in any event within fifteen (15) Days (or such other period as is mutually agreed by Owner and Contractor) after receipt from Owner of a request for a change or Notice of Owner’s acceptance under Section 12.2.1, Contractor shall submit to Owner a proposal for implementing the change indicating the estimated change to the Target Price and/or the Project Schedule, as applicable. If Owner (having consulted with the Independent Engineer in the case of a Material Change) agrees that the Contractor’s proposal should be implemented, Owner (having consulted with the Independent Engineer in the case of a Material Change) shall issue a Change Order incorporating such proposal. Upon receiving such Change Order, Contractor shall diligently perform the change in accordance with the terms thereof.

12.2.3 Contractor’s proposal required pursuant to Section 12.2.2 shall consist of: (a) a detailed material take-off with supporting calculations in accordance with the pricing structure herein, for pricing the change, (b) revisions, if any, to the Drawings and Specifications, (c) a schedule for the work associated with the proposed change, (d) the effect, if any, to the Target Price and/or the Project Schedule, as applicable, (e) the effect, if any, of the change on the Work, including the Performance Tests and/or Demonstration Tests (or protocol therefor), (f) changes, if any, to any right, liability or obligation of a Party or any other provision hereof and (g) changes, if applicable, to any Applicable Deadline.

12.2.4 Contractor’s supporting calculations shall show: (a) the estimated unit quantities, home office and Job Site manpower, Material usage and services to be added and/or deducted by size, type and/or amount provided; (b) the industry estimating reference or other basis used to determine prices, man-hours per unit of installed Materials, rental rates and other similar cost standards; (c) detailed cost breakdown for manpower, engineering and Materials; (d) the Contractor’s Margin; and (e) impacts, if any, to the Critical Path.

12.2.5 Contractor shall not suspend performance of this Agreement during the review and negotiation of any change (regardless of whether such change is proposed by Contractor or Owner), except as may be directed by Owner. Contractor shall commence and perform the changed Work specified in the Change Order issued by Owner under Sections 12.2.2 or 12.3.1, on a cost-reimbursable basis, using Exhibit B-1 and Exhibit C as the basis for such compensation. In the event Owner and Contractor are unable to reach agreement for pricing of a change, or time for performance of changed Work, disagreements regarding such Change Order shall be subject to the dispute resolution procedures set forth in Article 36. Pending resolution of the Dispute, Contractor shall perform the Work as specified in such Change Order and Owner shall continue to pay Contractor all Direct Costs and Contractor’s G&A and Contractor’s Margin applicable thereto associated with such Change Order.

 

12.3

DISPUTED CHANGES.

12.3.1 If Owner (having consulted with the Independent Engineer in the case of a Material Change) disagrees in any way with any proposal of Contractor under Section 12.2, Owner may issue a Change Order to Contractor changing the Work and/or Project Schedule, which Change Order is executed solely by Owner, and Contractor shall be entitled to payment as set forth in Section 12.2.5 and the impact to the Target Price and/or the Project Schedule, as applicable, shall be resolved pursuant to the dispute resolution procedures set forth in Article 36.

 

61


 

12.3.2 Any Change Order executed solely by Owner shall be accompanied by the Contractor’s proposal marked to show Owner’s modifications thereto and shall order Contractor to implement the change in accordance with the proposal as modified by Owner.

 

12.4

CHANGES DUE TO UNKNOWN SUBSURFACE CONDITIONS.

12.4.1 Contractor shall be entitled to receive a Change Order to the extent that it encounters subsurface conditions including geotechnical conditions, archaeological artifacts, fossils, underground utilities or manmade structures which materially differ from, or were not disclosed or provided to Contractor by Owner in Exhibit M or the Geotechnical Reports or which were not identified by Contractor (or were not reasonably inferable or foreseeable) on the basis thereof, that (a) cannot be safely removed by heavy equipment present at the Job Site at no additional cost and without delay to Contractor, (b) are not Job Site Conditions and (c) cause an increase in the cost to complete the Work or cause a delay in Contractor’s performance of any Critical Path activities, to the extent actually and demonstrably caused by the existence of such geotechnical conditions, archaeological artifacts, fossils, underground utilities or manmade structures.

12.4.2 In the event Contractor encounters any conditions listed in Section 12.4.1 at the Job Site, Contractor shall leave such sites untouched and protected by fencing and shall immediately stop any Work affecting the area. Contractor shall notify Owner of any such discovery as soon as practicable, and Contractor shall carry out Owner’s instructions for dealing with the same. Contractor shall prevent its personnel, its Subcontractors’ personnel, the Agent For Contractors’ personnel and any other Persons from removing or damaging any such article or thing.

 

12.5

INFORMATION REQUESTS.

Owner may request that Contractor provide written information (prior to the issuance of a request for change) regarding the effect of a contemplated change on (a) the Work or the requirements set forth in Exhibit A, (b) the Target Price, (c) the Project Schedule, (d) the Critical Path, (e) any Applicable Deadline, (f) the Demonstration Tests or Performance Tests or (g) any right, liability or obligation of Contractor hereunder. The purpose of such a request will be to determine whether or not a change will be requested. Contractor shall provide the requested information within fourteen (14) Days after the receipt of said request. Such an information request by Owner is not a Change Order and shall not be construed to authorize Contractor to commence performance of the contemplated change in the Work.

 

13.

PROJECT SCHEDULE AND MONTHLY PROGRESS REPORTS.

 

13.1

GENERAL.

Contractor shall prosecute the Work in accordance with or in advance of the Project Schedule; provided, however, that any failure of Contractor to adhere to the Project Schedule, for reasons which are not otherwise excused hereunder, shall not limit or otherwise reduce its obligations or liabilities hereunder.

 

62


 

13.2

PROJECT SCHEDULE.

13.2.1 Contractor shall develop, deliver and maintain the Project Schedule in accordance with Exhibit E. The Project Schedule shall be the reference schedule for the duration of the Work, and shall be in the form of Exhibit D.

13.2.2 Except as provided in Article 12 or otherwise expressly in accordance with Exhibits D and E, Contractor shall not make any alterations to the Project Schedule. During the performance of the Work, Contractor and Owner (including Owner’s Representative or his designee, and any other Persons designated by Owner, and the Contractor’s Key Personnel) shall, at a minimum, conduct meetings as provided in Exhibit E for the purpose of reviewing the progress of the Work, the latest Monthly Progress Report, the Quality Management Plan, the HSSE Program, the Contractor’s, Subcontractors’ and Agent For Contractors’ adherence to the requirements set forth in Exhibit A, the Critical Path and the Project Schedule as well as the status of any claims on the Facility, the Job Site or the Work and claims submitted pursuant to the terms of this Agreement.

 

13.3

MONTHLY PROGRESS REPORTS.

Contractor shall prepare and submit a monthly report meeting the requirements of Exhibit I (each, a “Monthly Progress Report”) to Owner, Owner’s Representative and the Independent Engineer with each Request for Payment but in no event later than the tenth (10th) day of each month. Submission of Monthly Progress Reports shall continue until Contractor has completed all Work that is known to be outstanding at the time of Final Completion. Monthly Progress Reports shall include information relating to the performance of the Owner Contractors and the other information set forth in Exhibit I. The Parties agree that slippages in the Critical Path caused by Contractor, its Subcontractors or Agent For Contractors may be remedied by recovery plans and acceleration plans in accordance with Section 16.3, consisting of critical services, expediting of critical Material and equipment, the addition of productive construction equipment, additional competent supervision and other similar beneficial resources. It is further agreed that slippages in the Project Schedule known to Contractor will not be concealed from Owner, the Independent Engineer or the Lenders in the monthly reports.

 

14.

TRAINING.

Contractor shall be responsible for training Owner’s and/or its Affiliate’s regular operating personnel listed in Exhibit Q in accordance with Exhibit G. Training aids shall be provided by Contractor as required to adequately present the subject material. The general topics of the training will encompass reasonable information necessary for efficient and proper operation of each LNG Production System and the Facility, including operation, maintenance and repair. Training will consist of classroom, on-the job operational training and training using simulation software as necessary to comply with the requirements of this Article 14 and the requirements set forth in Exhibit A. Contractor shall design and submit an outline of a training program to Owner within one hundred eighty (180) Days after the Notice to Proceed Date and a detailed training program one hundred eighty (180) Days prior to commencement of training. Owner shall have a period of thirty (30) Days following submittal to it of the training program outline or detailed program to approve or comment upon each submittal. Contractor shall effect changes in response to Owner’s

 

63


 

comments and resubmit the training procedures for Owner’s review and approval within fifteen (15) Days of receipt of such comments from Owner, and Owner shall have a further period of fifteen (15) Days following such resubmittal to approve. Contractor shall conduct at least one (1) full course of training prior to the start of any Pre-Commissioning activities. The training documentation and instruction shall be in the English language. All of the Contractor’s training personnel will speak fluent English as reasonably determined by Owner. All training provided by Contractor shall stress strict compliance with the operation and maintenance manuals, operating instructions, system checklists and/or procedures. If any of the Contractor’s training personnel repeatedly allow, encourage or demonstrate any attitudes or work practices that are not in strict compliance with the operation and maintenance manuals, operating instructions, system checklists and/or procedures, such training personnel shall be replaced by Contractor.

 

15.

TESTING.

 

15.1

FACTORY TESTS.

Contractor shall perform all customary or required factory tests of all of the Materials in accordance with the requirements set forth in Exhibit A or Exhibit R or by Owner Standards. Contractor shall issue a test memorandum to Owner no later than thirty (30) Days prior to the commencement of each factory test, which memorandum shall describe the factory test to be performed, the applicable item of Material being tested, the standards and method of testing, and the testing facility’s capabilities and shall state a proposed test date. Owner’s Representative and the representative of the Independent Engineer shall be permitted to attend and participate in all such factory tests. Contractor shall provide the results of such required factory tests to Owner within ten (10) Days of the completion of each such factory test. Successful completion of such factory test shall be a precondition to shipment of the tested item of Material.

 

15.2

DEMONSTRATION TESTING.

15.2.1 Contractor shall submit Demonstration Test procedures and a level 3 Demonstration Test schedule at least sixty (60) Days before commencement of the Demonstration Tests in accordance with (and as defined in) Exhibit R. Prior to commencing any Demonstration Tests, Contractor shall submit to Owner a certification that the Facility is free of known Defects and Deficiencies and ready for performance of the Demonstration Tests in accordance with Exhibit R. Owner shall be given at least ten (10) Business Days’ prior Notice by Contractor of the commencement of any Demonstration Tests so that Owner can schedule its and/or its Affiliate’s personnel to witness such Demonstration Tests.

 

15.3

PERFORMANCE TESTING.

15.3.1 Unless Owner otherwise consents in writing (which consent may be withheld in Owner’s sole discretion and for any reason), Contractor must complete all Demonstration Tests, as applicable, and remedy all Defects or Deficiencies, which have been identified by such Demonstration Tests, prior to the start of any Performance Tests.

 

64


 

15.3.2 Owner or its Affiliate will cause qualified and experienced personnel to be available to Contractor for use in executing the Performance Tests and any rerun thereof in compliance with this Agreement and Exhibit R. Contractor shall direct and remain responsible for the actions or omissions of the operation and maintenance personnel (including the personnel of Owner or its Affiliate) during the Performance Tests. In addition, Contractor shall provide the services necessary at the Job Site for the installation, start-up and performance of the Commissioning of each LNG Production System and the Facility and the running or rerunning of the Performance Tests in accordance with the requirements of the Performance Tests and the provisions hereof. The Contractor’s Representative shall have full authority to represent Contractor and to acknowledge Defects or Deficiencies in the Facility, direct the proper conduct of remedial actions relating to the performance of the Facility and the execution of the Performance Tests.

15.3.3 Contractor shall provide preliminary Notice to Owner and the Independent Engineer not less than ninety (90) Days prior to the date that Contractor expects the relevant Work and/or Owner Furnished Equipment and Materials to be ready for the Performance Tests. Contractor shall provide an additional Notice to Owner and the Independent Engineer not less than five (5) Business Days prior to the date that Contractor will perform the Performance Tests. The Performance Tests for an LNG Production System or the Facility, as applicable, shall be executed as soon as practicable after LNG Production System Mechanical Completion of such LNG Production System or Facility Mechanical Completion, as applicable, and completion of the Demonstration Tests, as applicable, for such LNG Production System or the Facility; provided that, at Owner’s direction, Contractor shall take into account the interim operations of the Facility by Owner and Owner’s contractual commitments to purchasers of LNG to be produced and loaded at the Facility in scheduling Performance Tests. For the avoidance of doubt, the Parties agree that LNG Production System Mechanical Completion of an LNG Production System or Facility Mechanical Completion, as applicable, will precede the start of the performance of the Demonstration Tests, as applicable, for such LNG Production System or the Facility and that the Demonstration Tests, as applicable, for an LNG Production System or the Facility will precede the start of the Performance Tests for such LNG Production System or the Facility. It is further agreed that Defects or Deficiencies affecting the safe, proper or reliable operation of an LNG Production System which are discovered prior to achieving LNG Production System Mechanical Completion of an LNG Production System or Facility Mechanical Completion, as applicable, will be remedied before starting the Demonstration Tests, as applicable, for such LNG Production System or the Facility and any such Defects discovered during the performance of the Demonstration Tests, as applicable, for such LNG Production System or the Facility will be remedied prior to the performance of the Performance Tests for such LNG Production System or the Facility. Defects or Deficiencies discovered during any Performance Tests may, in the sole, reasonable judgment of Owner, require remedy and a subsequent Performance Test; provided, that, if the immediately prior Performance Test was successfully passed, then any subsequent Performance Test shall not prevent Contractor’s achievement of LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable. Notices by Contractor certifying that each of the aforementioned stages have been completed in full compliance with this Agreement must be accepted by Owner in writing.

15.3.4 Contractor shall be responsible to perform all Work necessary, including to correct any Defects and Deficiencies, for the Facility to successfully pass the Performance Tests described in and to the extent required by Exhibit R (including the 72-hour Facility System Reliability Test which, for the avoidance of doubt, shall be conducted with no contribution or effect from LPS4 equipment) (the “Facility Performance Tests”). If: (a) Contractor performs the Facility Performance Tests in accordance with this Agreement and the Facility fails to successfully pass

 

65


 

all of the Facility Performance Tests [***] times, or (b) Contractor performs the Facility Performance Tests in accordance with this Agreement and the Facility fails to successfully pass all of the Facility Performance Tests within [***] days after the LPS4 Substantial Completion Date (the earlier to occur of such events, the “Make Good Commencement Date”), then from and after the Make Good Commencement Date Contractor shall be obligated hereunder to perform all Work necessary to successfully pass all of the Facility Performance Tests as soon as reasonably practicable following the Make Good Commencement Date, subject to any Owner Caused Delay impacting its performance after the Make Good Commencement Date, at its sole cost and expense. Notwithstanding anything contained herein to the contrary, Owner shall have no obligation to pay any Direct Costs, Contractor’s G&A or Contractor’s Margin incurred by Contractor after the Make Good Commencement Date in connection with such Work (excluding, for the avoidance of doubt, any Work that is necessary solely to facilitate the performance by an Owner Contractor of its warranty or make good obligations to Owner in respect of the Owner Furnished Equipment and Materials from and after the Make Good Commencement Date). Without limiting the foregoing, Contractor acknowledges and agrees that its obligation to perform all Work necessary to successfully pass all of the Facility Performance Tests is an absolute, unconditional, “must meet” obligation and is not subject to any limitation on liability or reduction by the payment of liquidated damages or otherwise. Upon successfully passing the Facility Performance Tests, Contractor shall be entitled to payment of its Direct Costs and Contractor’s G&A and Contractor’s Margin applicable thereto in connection with any Reimbursable Work performed after the Facility Substantial Completion Date.

15.3.5 During the Warranty Period, Owner may, or may require Contractor to, conduct a test of any item of Material, component or system that has required modification, repair or replacement under warranty. Such test shall include, where necessary or appropriate, additional Demonstration Tests or Performance Tests (as described in Exhibit R), in each case, having a scope and duration reasonably necessary to demonstrate the absence of any adverse effect.

15.3.6 If the completed Work, or any section thereof, fails to pass a test required hereunder, Owner may require such failed tests to be repeated under the same terms and conditions.

 

15.4

CORRECTION OF PERFORMANCE DEFECTS OR DEFICIENCIES.

15.4.1 At any time prior to LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable, Contractor shall advise Owner in writing of any (a) Defects or Deficiencies in or (b) defects or deficiencies in the Owner Furnished Equipment and Materials forming part of, such LNG Production System or the Facility, as applicable, that were discovered at any time or that occurred during the Performance Tests for such LNG Production System or the Facility. Contractor shall promptly commence and complete corrective measures to remedy such Defects or Deficiencies; provided, however, that, without prejudice to Contractor’s express obligations related to the Owner Furnished Equipment and Materials as set forth in the definition of “Work” such as integration and installation of Owner Furnished Equipment and Materials, Contractor has no obligation to correct defects or deficiencies in the Owner Furnished Equipment and Materials forming part of such LNG Production System or the Facility. All portions of the Work that contain Defects or Deficiencies not so corrected shall be repaired or removed from the Job Site if necessary. If Contractor fails to initiate correction of Work having such Defects or Deficiencies within seven (7) Days after discovery of such Defects

 

66


 

or Deficiencies, Owner may correct such Work, and Owner’s costs associated with uncovering, recovering, correcting and removing Work that contains Defects or Deficiencies, as well as modifying, removing, disassembling, uncovering, rebuilding, re-engineering, replacing or covering or otherwise handling all other Work affected by such Defects or Deficiencies, shall be included in the calculation of Total Costs. If Contractor does not, within ten (10) Days of Notice from Owner, remove or repair Work (or initiate removal thereof) which has Defects or Deficiencies, Owner may, in its discretion, remove, repair, store, sell or dispose of such Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. Contractor shall promptly provide Notice to Owner in writing that such corrective measures have been completed and shall specify in such Notice the date on which the LNG Production System or the Facility will be ready for the Performance Tests to be rerun. Contractor’s obligation to correct Defects or Deficiencies includes uncovering, recovering, correcting and removing Work that contains Defects or Deficiencies, as well as modifying, removing, disassembling, uncovering, rebuilding, re-engineering, replacing or covering or otherwise handling all other Work affected by such Defects or Deficiencies or the correction thereof.

15.4.2 In preparation for the effort to remedy such Defects or Deficiencies discovered after LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable, Owner shall provide personnel and Contractor shall supervise and direct such personnel in the disconnection of the Work from all piping and the cleaning, freeing of liquids, solids, explosives and combustibles, toxic and asphyxiant gases and otherwise making safe for performance of the repair work. Contractor shall promptly provide Notice to Owner in writing that such corrective measures have been completed and shall specify in such Notice the date on which the LNG Production System or the Facility will be ready for the Performance Tests to be rerun. If Contractor fails to initiate correction of Work having such Defects or Deficiencies within seven (7) Days after discovery of such Defects or Deficiencies, Owner may correct such Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. If Contractor does not, within ten (10) Days of Notice from Owner, repair or remove Work (or initiate removal thereof) which has Defects or Deficiencies, Owner may, in its discretion, remove, repair, store, sell or dispose of such Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

16.

TIME FOR PERFORMANCE AND SCHEDULE.

 

16.1

TIME FOR COMPLETION.

Contractor shall cause (a) each LNG Production System Substantial Completion Date to occur no later than the relevant LNG Production System Substantial Completion Deadline, (b) the Facility Substantial Completion Date to occur no later than the Facility Substantial Completion Deadline and (c) the Final Completion Date to occur no later than the Final Completion Deadline. If an Applicable Deadline shall be actually, demonstrably and adversely affected by an excusable event hereunder including Owner Caused Delay or Force Majeure Event, and to the extent such delay could not be avoided or mitigated by Contractor (without Contractor having to incur material Non-Reimbursable Costs), then such Applicable Deadline shall be adjusted pursuant to a Change Order; provided that Contractor shall have provided proper Notice to Owner in accordance with Section 12.1.2 and that the conditions set forth in Section 12.1.3 (if applicable) are satisfied. Contractor will design (to the extent included in the Work) and integrate the Facility, supply all

 

67


 

necessary Materials, and schedule its activities (including the scheduling of deliveries as early as practical) taking into account the possible schedule impact of reasonably foreseeable delays and take all reasonably necessary measures to mitigate the effects of any such event enumerated in the preceding sentence and to cause the occurrence of LNG Production System Substantial Completion of each LNG Production System on or before the applicable LNG Production System Substantial Completion Deadline, the occurrence of Facility Substantial Completion on or before the Facility Substantial Completion Deadline and the occurrence of Final Completion on or before the Final Completion Deadline, and to timely perform Corrective Work during the Warranty Period. No delay of an Applicable Deadline shall prejudice any right Owner may have under this Agreement to terminate this Agreement pursuant to the terms of Article 32. Owner’s requirement of correction of any Defect or Deficiency shall not under any circumstances be construed as interference with the Contractor’s performance of the Work. Contractor agrees to use commercially reasonable efforts to exhaust every reasonable repair and replacement alternative in order for the Facility to meet the requirements set forth in this Agreement, including Exhibit A.

 

16.2

FAILURE TO MITIGATE.

If, after an event that has caused Contractor to suspend or delay performance of the Work, Contractor has failed to take such action as Contractor could lawfully and reasonably initiate to remove or relieve either the cause thereof or its direct or indirect effects without incurring material Non-Reimbursable Costs, Owner may, in its sole discretion and after Notice to Contractor, initiate such reasonable measures as will be designed to remove or relieve such event or its direct or indirect effects and thereafter require Contractor to resume full or partial performance of the Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. No action by Owner pursuant to this Section 16.2 shall relieve or excuse Contractor of any of its obligations under this Agreement or constitute the basis for a Change Order.

 

16.3

RECOVERY AND ACCELERATION OF WORK.

16.3.1 In addition to Contractor’s own recovery plans, if Owner reasonably believes that Contractor will not achieve an Applicable Deadline, then Owner may provide a Notice to Contractor requiring Contractor to propose an additional recovery plan and implement it. Contractor shall be required to present a detailed recovery plan for Owner’s review and concurrence within five (5) Business Days of its receipt of the Notice described in the immediately preceding sentence, which such recovery plan shall include at a minimum the methods of expediting the Work, the additional equipment and tools to be provided and the increased manpower, technology, work shifts and supervision anticipated. Owner may suggest additional resources be added to the recovery plan but such suggestions shall in no way be deemed to limit or otherwise reduce the Contractor’s obligations and liabilities hereunder or Owner’s rights hereunder. If Owner directs Contractor to implement a recovery plan, then Contractor shall implement the recovery plan as provided in this Section 16.3.1. Contractor shall not be entitled to an increase in the Target Price in connection with any recovery plan, unless and to the extent that the recovery plan was necessitated by an event for which (a) the Contractor obtains relief through a Change Order and (b) is entitled to an adjustment to the Target Price, as applicable.

 

68


 

16.3.2 Notwithstanding anything contained herein to the contrary, Owner shall have the right to direct that the Work be accelerated by means of reasonable overtime, additional crews or additional shifts, notwithstanding that the progress of the Work was in accordance with the established Project Schedule. Contractor shall promptly provide to Owner for its approval a plan for such acceleration, including its recommendations for the most effective and economical acceleration, together with such information as Owner shall reasonably require to substantiate the basis of the incremental cost. Prior to the Contractor’s commencement of the accelerated Work, Owner and Contractor shall mutually agree upon the plan for acceleration and the Contractor’s acceleration cost estimate, to be set forth in a Change Order. In addition to Owner’s acceleration rights, Contractor is entitled to request an acceleration plan to be approved by Owner. Should Owner approve such plan, Owner and Contractor shall mutually agree upon the plan for acceleration and the Contractor’s acceleration cost estimate, to be set forth in a Change Order.

 

17.

SUSPENSION OR REJECTION OF THE WORK.

 

17.1

GENERAL.

17.1.1 Owner may at any time or from time to time, and for any reason, suspend performance of the Work or any portion thereof by giving a Suspension Notice to Contractor. Such suspension shall continue for the period (the “Suspension Period”) specified by Owner in the Suspension Notice. At any time after the effective date of the suspension, Owner may require Contractor to resume performance of the Work. In the event a Suspension Notice is issued by Owner under this Section 17.1.1, Contractor shall take such action as is necessary to protect, store and secure the Work, or part thereof, against any deterioration, loss or damage, and if Owner notifies Contractor of the anticipated length of such suspension, Contractor shall use reasonable efforts to delay the performance of any Work to be performed by any Subcontractor or Agent For Contractor.

17.1.2 If Owner reasonably believes that Contractor is (i) in violation of applicable Laws or any Permit and such violation has a material impact on the Facility, (ii) performing Work which has Defects or Deficiencies, is failing to correct Work which has Defects or Deficiencies in a timely manner as practicable, is failing to take the proper precautions at any time when dangerous conditions exist or (iii) otherwise in material breach of this Agreement, then Owner may, by Notice to Contractor, order Contractor to suspend performance of the Work affected by any such failure under this Section 17.1.2 by giving a Suspension Notice to Contractor. Such suspension shall continue for the Suspension Period specified in the Suspension Notice, subject to the following sentence. Upon receipt of such Suspension Notice, Contractor shall (A) suspend performance of the Work to the extent set forth in such Suspension Notice and shall not resume such Work unless and until Contractor and Owner, acting reasonably, have agreed on those actions to be taken by Contractor to eliminate or cure the cause of such Suspension Notice, and (B) take such action as is necessary to protect, store and secure the Work, or part thereof, against any deterioration, loss or damage, and if Owner notifies Contractor of the anticipated length of such suspension, Contractor shall use reasonable efforts to delay the performance of any Work to be performed by any Subcontractor or Agent For Contractor. Upon resumption of the Work, Contractor shall take all actions as and when required by such agreement with Owner.

17.1.3 Contractor may, upon prior Notice to Owner, suspend the Work in the event Owner fails to make payment of any reasonably undisputed payment to the Contractor specified in such Notice within thirty (30) days of the date such payment is due, and any such suspension shall entitle Contractor to an adjustment in the Applicable Deadlines and the Target Price, to the extent Contractor incurs Direct Costs as a direct result of such suspension.

 

69


 

17.2

COMPENSATION TO CONTRACTOR FOR SUSPENSION.

17.2.1 In the event of a suspension by Owner pursuant to Section 17.1.1, Owner shall issue a Change Order to (a) compensate Contractor for the additional Direct Costs, Contractor’s G&A and the Contractor’s Margin attributable solely to a suspension of items of Work that are documented by Contractor to the satisfaction of Owner and the Independent Engineer; (b) adjust the Target Price to reflect such additional amounts; and (c) adjust the Project Schedule for any delay in the Contractor’s performance of any Critical Path activities, which, in each case, was actually and demonstrably caused by such suspension.

17.2.2 All claims by Contractor for compensation under this Section 17.2 must be made monthly during the Suspension Period and within forty-five (45) Days after the end of the Suspension Period, or Contractor shall be deemed to have waived its rights for compensation with respect thereto. Amounts payable by Owner under this Article 17 shall be paid to Contractor in accordance with Article 6.

 

17.3

REJECTION OF WORK.

Owner shall have the right to inspect Materials or the Work at Contractor’s workshop and at any Subcontractor’s or Agent For Contractor’s workshop, the Job Site, or at such other places as otherwise may be appropriate, and, prior to LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable and subject to Contractor’s warranty obligations thereafter, to reject items of Materials or any portion of the Work that has Defects or Deficiencies. Owner shall specify in writing to Contractor the portion of the Materials or portion of Work that it proposes to reject and, prior to actual rejection, Contractor shall have a right to remedy any such Defects or Deficiencies to Owner’s satisfaction. Owner shall have the right to utilize any rejected portion of the Materials or the Work until such time as replacement Material is incorporated into the Facility. These rights shall not be deemed to limit Owner’s rights under Section 15.4.

 

17.4

CORRECTION OF WORK OR MATERIAL.

Contractor shall promptly correct all Materials or Work rejected by Owner as having Defects or Deficiencies observed before commencement of the Warranty Period of the applicable LNG Production System or any extension thereof, and whether or not fabricated, installed or completed. All portions of the Material or Work that contain Defects or Deficiencies not so corrected shall be repaired or removed from the Job Site if necessary, by Owner in accordance with Section 17.5. Contractor is responsible for removing Material or any portion of the Work that contain Defects or Deficiencies, as well as modifying, removing, disassembling, uncovering, rebuilding, replacing or covering or otherwise handling all other Material or Work affected by such Defects or Deficiencies or the correction thereof. These obligations shall not be deemed to limit Contractor’s obligations under Section 15.4. No action by Owner pursuant to this Section 17.4 shall relieve or excuse Contractor of any of its obligations under this Agreement or constitute the basis for a Change Order.

 

70


 

17.5

FAILURE TO CORRECT MATERIAL.

If Contractor fails to initiate correction of Materials or Work having Defects or Deficiencies in accordance with Section 17.4 within five (5) Days of Notice from Owner, Owner may correct such Materials or Work without relieving Contractor of any of its warranty obligations hereunder, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

17.6

OTHER MATERIAL OR WORK DAMAGED.

Owner shall bear the full cost of making good all Materials or any part of the Facility destroyed or damaged by reasonable removal either by Owner as provided in Section 17.5 or by Contractor, but Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

18.

LNG PRODUCTION SYSTEM COMPLETION.

 

18.1

LNG PRODUCTION SYSTEM MECHANICAL COMPLETION.

18.1.1 Upon satisfaction of the conditions set forth in this Section 18.1 for an LNG Production System, Contractor shall give Notice to Owner that LNG Production System Mechanical Completion for such LNG Production System has occurred, which shall only be when all of the following items set forth in this Section 18.1 have occurred:

(a) Contractor has certified to Owner that the Work for such LNG Production System has been designed and constructed and is ready for operation or operating in accordance with the requirements set forth in Exhibit A, applicable Laws and Permits and Owner Standards, and have performed all of its obligations under this Agreement then to be performed in relation to such LNG Production System, and the Work is free of all known Defects and Deficiencies (other than the Punch List Items);

(b) Owner has received required operations, maintenance and spare parts manuals and instruction books necessary to operate such LNG Production System in a safe, efficient and effective manner, and Contractor has completed the training program required by Article 14;

(c) Contractor has prepared and submitted for Owner’s approval, and Owner has approved, a safety transition plan for the Facility consistent with the requirements set forth in the HSSE Program;

(d) Contractor has performed all other provisions hereof and delivered all items required hereby to achieve LNG Production System Mechanical Completion of such LNG Production System in a manner reasonably satisfactory to Owner; and

(e) Contractor has delivered to Owner the LNG Production System Mechanical Completion Certificate.

 

71


 

18.1.2 At such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 18.1.1 has been completed with respect to an LNG Production System, Owner shall sign the LNG Production System Mechanical Completion Certificate for such LNG Production System, which shall be dated the date the final item set forth in Section 18.1.1 occurs with respect to such LNG Production System, as determined by Owner.

18.1.3 Notwithstanding anything to the contrary contained herein, Contractor shall retain care, custody, and control of an LNG Production System Handover Package until the corresponding LNG Production System Substantial Completion Date.

 

18.2

LNG PRODUCTION SYSTEM RFSU.

18.2.1 Without limitation of any scheduling requirement contained herein, Contractor shall give Owner at least one hundred eighty (180) Days’ prior Notice to the date on which Contractor expects to achieve LNG Production System RFSU for each LNG Production System. Not less than ninety (90) Days and not more than one hundred twenty (120) Days after each such Notice, Contractor shall give Owner a second Notice specifying the seven (7) Day period during which Contractor expects to achieve LNG Production System RFSU for the applicable LNG Production System. At such time as each LNG Production System achieves LNG Production System RFSU, Contractor shall certify to Owner in the form of an LNG Production System RFSU Certificate that all requirements under this Agreement for LNG Production System RFSU with respect to the applicable LNG Production System have been satisfied. Each LNG Production System RFSU Certificate shall be accompanied by other supporting documentation as may be required under this Agreement to establish, to Owner’s reasonable satisfaction, that the requirements for LNG Production System RFSU have been met, including that Owner has received from Contractor all final Permits relating to such LNG Production System and required to be obtained by Contractor and, if final Permits are not available, all temporary Permits to enable Owner to operate such LNG Production System uninterrupted until such time as such final Permits are obtained. Owner shall by Notice to Contractor confirm whether it accepts or rejects each LNG Production System RFSU Certificate within twenty-four (24) hours following Owner’s receipt thereof. Acceptance of LNG Production System RFSU with respect to an LNG Production System shall be evidenced by Owner’s signature on the applicable LNG Production System RFSU Certificate. The date of LNG Production System RFSU shall be based upon, and the date of Owner’s acceptance of LNG Production System RFSU shall be deemed to have occurred on, the date listed on the applicable LNG Production System RFSU Certificate; provided that all requirements under this Agreement for LNG Production System RFSU were achieved on such date listed on the applicable LNG Production System RFSU Certificate. If Owner does not agree that LNG Production System RFSU has occurred with respect to a particular LNG Production System, then Owner shall state the basis for its rejection in reasonable detail in such Notice. If the Parties do not mutually agree on when and if LNG Production System RFSU with respect to an LNG Production System has occurred, the Parties shall thereupon promptly and in good faith confer and make all reasonable efforts to resolve such issue. In the event such issue is not resolved within two (2) Business Days of the delivery by Owner of its Notice to Contractor, the Parties shall resolve such Dispute in accordance with Article 36. Owner’s acceptance of LNG Production System RFSU with respect to an LNG Production System shall not relieve Contractor of any of its obligations to perform the Work in accordance with the requirements of this Agreement.

 

72


 

18.2.2 After Owner has accepted the System Turnover Packages, LNG Production System Mechanical Completion has occurred, and the start-up and Pre-Commissioning test reports have been provided to Owner for one (1) or more LNG Production Systems and Contractor has resolved Owner and the Contractor’s lists of Defects or Deficiencies for such LNG Production System(s) (other than the Punch List Items), if any, Contractor shall schedule the cooldown of Tank One or Tank Two, as applicable (each an “LNG Storage Tank Cooldown”). Contractor shall provide Owner with Notice at least one hundred eighty (180) Days’ prior to the date on which Contractor expects LNG Storage Tank Cooldown to occur and shall specify in such Notice the amount of Feed Gas required for LNG Storage Tank Cooldown. Not less than ninety (90) Days and not more than one hundred twenty (120) Days after such Notice, Contractor shall give Owner a second Notice specifying the seven (7) Day period during which Contractor expects LNG Storage Tank Cooldown to occur and confirming the amount of Feed Gas required for LNG Storage Tank Cooldown.

 

18.3

LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION.

18.3.1 Upon compliance with all other conditions set forth in this Section 18.3, Contractor shall give Notice to Owner that LNG Production System Substantial Completion of an LNG Production System has occurred, which shall only be when all of the following items set forth in this Section 18.3 have occurred, unless Owner agrees in writing to waive any such requirements:

(a) all of the conditions for LNG Production System Mechanical Completion of such LNG Production System set forth in Section 18.1 have been met, and Owner has received and accepted the LNG Production System RFSU Certificate for such LNG Production System in accordance with Section 18.2;

(b) Owner has received the relevant System Turnover Packages demonstrating that Contractor has successfully completed all of the Pre-Commissioning and Commissioning of such LNG Production System;

(c) such LNG Production System is ready for normal, continuous and safe operation with the complement of personnel contemplated in Exhibit Q, and Contractor has corrected all Defects and Deficiencies (other than the Punch List Items);

(d) the Performance Tests for such LNG Production System have been satisfactorily completed in accordance with Exhibit R; and

(e) Contractor has delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 18.3.1.

18.3.2 At such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 18.3.1 has been completed with respect to an LNG Production System, Owner shall issue to Contractor a certificate stating the LNG Production System Substantial Completion Date for such LNG Production System, which date shall be the date that Contractor delivered to Owner a certificate certifying the satisfaction of each of the items in Section 18.3.1.

 

73


 

19.

FACILITY COMPLETION.

 

19.1

FACILITY MECHANICAL COMPLETION.

19.1.1 Upon satisfaction of the conditions set forth in this Section 19.1, Contractor shall give Notice to Owner that Facility Mechanical Completion has occurred, which shall only be when all of the following items set forth in this Section 19.1 have occurred:

(a) all the conditions for LNG Production System Mechanical Completion for all the LNG Production Systems set forth in Section 18.1 have been met, and Owner has received and accepted the LNG Production System RFSU Certificate for all of the LNG Production Systems in accordance with Section 18.2;

(b) Contractor has certified to Owner that the Facility has been designed (to the extent included in the Work), integrated and constructed and is ready for operation or operating in accordance with the requirements set forth in Exhibit A, applicable Laws and Permits and Owner Standards, and has performed all of its obligations under this Agreement then to be performed, and the Work is free of all Defects and Deficiencies (other than the Punch List Items);

(c) Owner has received from Contractor all final Permits required to be obtained by Contractor and, if final Permits are not available, all temporary Permits to enable Owner to operate the Facility uninterrupted until such time as such final Permits are obtained;

(d) Contractor has performed all other provisions hereof and delivered all items required hereby to achieve Facility Mechanical Completion in a manner reasonably satisfactory to Owner; and

(e) Contractor has delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 19.1.1.

19.1.2 At such time as Owner and the Independent Engineer have confirmed that each of the foregoing matters have been completed, Owner shall issue to Contractor a certificate stating the Facility Mechanical Completion Date. Facility Mechanical Completion shall be deemed to occur on the date the final item set forth in Section 19.1.1 occurs, as determined by Owner, and not the date such certification is received.

 

19.2

FACILITY SUBSTANTIAL COMPLETION.

19.2.1 Upon compliance with all other conditions set forth in this Section 19.2.1, Contractor shall give Notice to Owner that Facility Substantial Completion has occurred, which shall only be when all of the following items set forth in this Section 19.2.1 have occurred:

(a) all of the conditions for Facility Mechanical Completion set forth in Section 19.1 have been met, and Owner has received and accepted the LNG Production System RFSU Certificate for each LNG Production System in accordance with Section 18.2;

(b) all of the conditions for LNG Production System Substantial Completion set forth in Section 18.3 have been met for all of the LNG Production Systems;

 

74


 

(c) Contractor has made available to Owner at the Job Site all special tools and Spare Parts in accordance with Section 3.9.1 (any reorders to be a Punch List Items in accordance with Section 19.5);

(d) Contractor has successfully completed all of the Demonstration Tests for the Facility, as verified by reports delivered by Contractor to Owner;

(e) Owner has received the System Turnover Packages demonstrating that Contractor has successfully completed all of the Commissioning for the Facility;

(f) the Facility is ready for normal, continuous and safe operation with the complement of personnel contemplated in Exhibit Q, and Contractor has corrected all Defects and Deficiencies (other than the Punch List Items);

(g) Contractor has completed the training program required by Article 14;

(h) Contractor has performed all other provisions hereof required for normal, continuous and safe operation and delivered all items required hereby (except any Punch List Items or other obligations of Contractor not intended to be fully performed at Facility Substantial Completion) required by this Agreement;

(i) (A) the Performance Tests for the Facility have been satisfactorily completed in accordance with Exhibit R;

(j) Contractor has paid all amounts to Owner then due and payable hereunder, or Owner has elected to set-off such amounts against any payment that may be owed by Owner to Contractor;

(k) Contractor has provided Owner a complete list of the Punch List Items;

(l) Contractor has prepared, and submitted to Owner’s Representative the operation and maintenance manuals, operating instructions, system checklists and/or procedures required to be provided by Contractor under Exhibit J in the English language in sufficient detail for Owner to operate, maintain, dismantle, reassemble, adjust and repair the Facility; and

(m) Contractor has delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 19.2.1.

19.2.2 The Facility shall be fully taken over by Owner at such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 19.2.1 has been completed and Owner issues to Contractor a certificate stating the Facility Substantial Completion Date which shall be the date the final item set forth in Section 19.2.1 occurs with respect to the Facility, as determined by Owner, and not the date the certification is received.

 

75


 

19.3

READY FOR SHIP LOADING.

Without limiting the foregoing or any other scheduling requirements contained herein, Contractor shall provide Owner (a) at least one hundred eighty (180) Days’ prior Notice of the day on which Contractor expects to be ready for Owner or its Affiliate to perform the Loading Rate Test, and (b) a second Notice specifying the date on which Contractor expects to be ready for the Loading Rate Test, which second Notice shall be given no later than sixty (60) Days prior to such date. Owner shall cause an LNG Tanker to be available, after the date in such second Notice; provided that Owner is not required to schedule such LNG Tanker until (a) there is sufficient LNG in storage in the LNG Storage Tanks to perform the Loading Rate Test and (b) Owner has the ability and an economic reason to export such LNG; provided, further, that if Owner’s decision not to schedule an LNG Tanker adversely impacts commissioning or testing activities, then Contractor shall be entitled to a Change Order for such decision if and to the extent it meets the requirements for an Owner Caused Delay. Owner shall give Contractor fourteen (14) Days prior written notice of a five (5) Day period in which the LNG Tanker will be available for the Loading Rate Test. Contractor shall assist Owner in identifying prospective LNG Tanker operators to conduct assurance and vetting of the marine terminal, and shall provide reasonable access to the Job Site to such operators and to other LNG Tanker operators who are anticipated to use the Facility to conduct such assurance and vetting activities.

 

19.4

FINAL COMPLETION.

19.4.1 Final Completion of the Facility shall occur no later than the Final Completion Deadline. In order to achieve Final Completion, Contractor must have:

(a) met all the conditions for Facility Substantial Completion set forth in Section 19.2;

(b) completed a Facility final clean-up including removal from the Job Site of all construction debris, bulk construction materials, storage trailers, temporary facilities, scaffolding, temporary protection and other impediments that would interfere with the normal operation and maintenance of the Facility, and Contractor has delivered the Facility in a clean condition satisfactory to Owner in accordance with the procedures set forth in Exhibit A;

(c) completed all Punch List Items, which Punch List Items shall be promptly completed upon receipt of such Material(s) or other event(s) and corrected all Defects and Deficiencies identified by Owner during the Performance Tests which Owner has decided do not require completion and re-running of the Performance Tests, and Owner must have accepted such corrections in writing;

(d) delivered to Owner all electronic files in the format designated by Owner, all Drawings and Specifications (including red-lined “as-built” drawings of such LNG Production System), test data and other technical information relating to such LNG Production System and required hereunder for Owner to operate and maintain such LNG Production System;

(e) delivered to Owner all as-built operations, maintenance and spare parts manuals and instruction books required to be delivered by Contractor that are necessary to operate the Facility in a safe, efficient and effective manner, and Contractor has completed the training program required by Article 14;

 

76


 

(f) delivered to Owner all electronic files in the format designated by Owner, all Drawings and Specifications (except final “as-built” drawings of the Facility, but including red-lined “as-built” drawings of the Facility), test data and other technical information required hereunder for Owner to operate and maintain the Facility;

(g) delivered to Owner final “as-built” drawings for the Facility as required by Section 3.8.43 and meeting the requirements of Exhibit J;

(h) removed all the Contractor’s, Subcontractors’, and Agent For Contractors’ personnel, supplies, equipment, waste materials, rubbish and temporary facilities from the Job Site (unless otherwise requested by Owner);

(i) delivered evidence satisfactory to Owner, including a Payment Status Affidavit from Contractor and all Major Subcontractors in the form of Exhibit F-15 and Exhibit F-16, respectively, and a final and unconditional release and waiver of liens from Contractor and all Major Subcontractors in the form of Exhibit F-3 and Exhibit F-4, respectively, that all claims, liens, security interests or encumbrances in the nature of mechanics’, labor or materialmen’s liens (if applicable) arising out of or in connection with the Job Site, Facility (or any portion thereof), any Materials, any land or improvements pertinent thereto or the performance by Contractor or any Major Subcontractor of the Work have been satisfied or discharged;

(j) performed all other provisions hereof and delivered all items required hereby (except any warranty or other obligation of Contractor not intended to be fully performed at Final Completion) in a manner satisfactory to Owner;

(k) paid all undisputed amounts to Owner then due and payable hereunder; and

(l) delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 19.4.1.

19.4.2 At such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 19.4.1 has been completed, Owner shall issue a Final Completion certificate. Notwithstanding the foregoing, nothing contained in this Section 19.4 shall relieve Contractor from performing any obligations remaining under this Agreement after Final Completion, including any of its warranty obligations hereunder.

 

19.5

PUNCH LIST ITEMS.

Notwithstanding anything to the contrary contained herein, at Owner’s sole discretion, Owner may approve the completion of Punch List Items after Final Completion. If Contractor does not promptly complete any remaining Punch List Item, Owner shall have the right to complete such item and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. Notwithstanding anything to the contrary contained herein, however, if the completion of any Punch List Items requires that an LNG Production System or the Facility be shut down or its output curtailed, Owner shall have the option of completing such Punch List Items itself, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

77


 

20.

WARRANTY FOR DEFECTS.

 

20.1

IN GENERAL.

20.1.1 As further described herein, Contractor shall repair or replace all Defects and Deficiencies prior to the commencement of the Warranty Period. Upon commencement of the Warranty Period, Contractor shall be required to perform all Corrective Work (defined below).

20.1.2 During the Warranty Period, Contractor shall, as soon as practicable, complete any Work that is outstanding at Final Completion and shall be responsible for performing Corrective Work which may appear or occur during the Warranty Period or any extension thereof.

20.1.3 During the Warranty Period and subject to Section 20.1.4, Contractor shall make good the Defects or Deficiencies in the Work promptly and on an expedited basis whether by repair, replacement or otherwise (the “Corrective Work”). In the event Contractor utilizes spare parts owned by Owner in the course of performing the Corrective Work or Work as provided in Section 20.1.4, Contractor shall supply Owner with new spare parts equivalent in quality and quantity to all such spare parts used by Contractor as soon as possible following the utilization of such spare parts.

20.1.4 If Contractor is obligated to repair, replace or renew a Serial Defect, Contractor shall undertake a technical analysis of the problem and correct the “root cause” unless Contractor can demonstrate to Owner’s satisfaction that there is not a risk of the reoccurrence of such problem. Contractor’s obligations under this Article 20 shall not be impaired or otherwise adversely affected by any actual or possible legal obligation or duty of any Subcontractor or Agent For Contractor, in each case, to Contractor or Owner concerning any Defect or Deficiency. No such correction or cure, as the case may be, shall be considered complete until Owner shall have reviewed and approved such remedial work in accordance with this Agreement.

20.1.5 Contractor shall have no obligation hereunder to correct Defects and Deficiencies in the Work relating to site preparation activities in the area described in Exhibit A.

 

20.2

SPECIFIC WARRANTIES.

In particular, Contractor warrants to Owner that:

20.2.1 Contractor shall perform the Work in full compliance with the terms and conditions set forth herein;

20.2.2 the Materials and the Work shall be designed, manufactured, engineered, constructed, completed, pre-commissioned, commissioned, tested and delivered in accordance with this Agreement;

20.2.3 the Materials and the Work shall be designed, manufactured, engineered, constructed, completed, tested and delivered, in a workmanlike manner and in accordance with this Agreement, Owner Standards, all Permits and approvals of Government Authorities, Applicable Codes and Standards and all applicable Laws;

 

78


 

20.2.4 the Work, including all Materials and each component thereof (a) shall conform to the specifications and descriptions set forth herein, (b) shall be new, complete, and of suitable grade for the intended function and use in accordance with this Agreement, (c) shall be free from defects (including latent defects) in design, material and workmanship, and (d) shall meet the requirements set forth in Exhibit A and the Agent For Contracts;

20.2.5 the Materials, or any component of Materials, shall be composed and made of only proven technology, of a type in commercial operation at the Effective Date; provided that Owner’s agreement for Contractor to use any Materials not in compliance with this Section 20.2.5 shall not relieve Contractor of any of its obligations under this Agreement;

20.2.6 if, prior to the expiration of the Warranty Period, two (2) or more of the same components of the Work experience a Defect of an identical or nearly identical nature that causes or could reasonably be expected to cause an outage or derating of the Facility (herein, a “Serial Defect”), then Contractor shall examine the cause of the Serial Defect and (i) undertake technical analysis of the underlying problem in order to determine (A) the root cause of such Serial Defect and (B) the repairs or replacements that may be required to avoid future occurrences of such Serial Defect, (ii) prepare and provide to Owner a written report setting forth the results of such analysis, (iii) promptly redesign if necessary and repair or replace any Materials, as necessary, and (iv) extend the Warranty Period for that portion of the Work that Contractor redesigned, repaired or replaced for an additional period of [***] months. Such warranty extension for Serial Defects is in lieu of and not in addition to the extension of the Warranty Period contemplated in Section 20.4.2.

20.2.7 Contractor shall, at all times during the Warranty Period, maintain sufficient personnel at Contractor’s offices to respond promptly to Owner’s request for diagnostic or warranty work. At any time during the Warranty Period, Contractor shall promptly and on an expedited basis perform such tests, inspections or other diagnostic services as may be reasonably requested by Owner. In the event that such diagnostic services reveal any Work not conforming to the Contractor’s Warranties, any and all such Work shall be corrected immediately as Corrective Work (the warranties set forth in Sections 20.2.1 to 20.2.7 inclusively are referred to collectively as the “Warranties”). The Warranties shall not include work performed under the Owner Contracts; and

20.2.8 Contractor shall, in the course of correcting any Defects or Deficiencies, do so (a) in good faith coordination with Owner’s schedule of operations so as to minimize any adverse effect on the operations of the Facility and (b) in accordance with the Warranty procedures set forth in this Article 20.

 

20.3

NOTICE OF DEFECTS OR DEFICIENCIES.

If any Defects, Deficiencies or resulting damage to the Work appear or arise from notifications by manufacturers of Material, Owner shall promptly notify Contractor of such Defects, Deficiency or damage, and Contractor shall perform the necessary repairs or replacements in accordance with its Warranty obligations. Owner shall be entitled to determine the existence of any Defects, Deficiencies or damage.

 

79


 

20.4

EXTENSION OF WARRANTY PERIOD.

20.4.1 The provisions of this Article 20 shall apply to all replacements or repairs carried out by Contractor as if the replacements and repairs had been taken over on the date they were completed. All Corrective Work shall be performed subject to the same terms and conditions under this Agreement as the original Work is required to be performed. Any change to parts or Materials that would alter the requirements of this Agreement or any Agent For Contract may be made only with prior written approval of Owner.

20.4.2 The Warranty Period for the Work or portion thereof that Contractor has replaced or repaired shall be extended by a period of [***] months from the date the replacement or repair is completed (and for successive periods of [***] months in the event of any Defect or Deficiency associated with any such replacement or repair), but in no event shall the Warranty Period extend beyond [***] months following Facility Substantial Completion.

 

20.5

FAILURE TO REMEDY DEFECTS.

If Contractor fails to commence any Corrective Work within a reasonable period of time not to exceed five (5) Days after receipt of Owner’s written notice to Contractor identifying and describing with reasonable specificity that portion of Work that has a Defect or Deficiency, or does not complete such Corrective Work on an expedited basis, Owner may, in its sole discretion and in addition to any other remedies that it has under this Agreement, proceed to do the Work and, subject to Section 16.2, notify Contractor of its intention to do so, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

20.6

REMOVAL AND OWNERSHIP OF DEFECTIVE WORK.

If the Defects, Deficiencies or resultant damage is such that it cannot be remedied expeditiously on the Job Site, Contractor may, with the prior written consent of Owner’s Representative or Owner, remove from the Job Site for the purposes of repair or replacement of any part of the Work which is defective, deficient or damaged.

 

20.7

FURTHER TESTS.

If the repair or replacement of any equipment or components of Work is such that it may affect the operation of the Work or any part thereof, then Owner may require that tests of such equipment or components or any affected part of the Work thereof be conducted by Contractor and repeated to the extent reasonably necessary. Such requirement shall be made by Notice within thirty (30) Days after the Defect or Deficiency is remedied. Such tests shall verify that the equipment or component or any affected part of the Work thereof, as the case may be, is at the same level of performance as existed prior to the need for repair or replacement.

 

20.8

RIGHT OF ACCESS.

Until the expiration of the Warranty Period, but only to the extent required to perform its obligations hereunder, Contractor shall have the right of reasonable access to all parts of the Work and to records of the working and performance of the Work, except as may be inconsistent with any reasonable security or safety restrictions of the Owner. Such right of access shall be

 

 

80


 

undertaken so as to minimize interference with the operation of the Facility. Access shall be granted to any duly authorized representative of Contractor whose name has been communicated in writing to Owner and who agrees to be bound by Owner Protocols and the confidentiality provisions of this Agreement in connection with such access. The Parties shall schedule corrections, repairs or replacements as necessary so as to minimize disruptions to the operation of the Facility.

 

20.9

SUBCONTRACTOR AND AGENT FOR CONTRACTOR WARRANTIES.

20.9.1 Contractor shall, for the protection of Contractor and Owner, use reasonable efforts to obtain from the Subcontractors such guarantees and warranties with respect to Work performed that are equal to or exceed those set forth in this Article 20 as applicable to their respective scopes of work and shall be made available and in the name of Owner and assignable to the Lenders to the full extent of the terms thereof. Subject to Section 23.1.4, Contractor shall enforce all Subcontractor and Agent For Contractor warranties in accordance with their terms so as to minimize the amount of Work Contractor may be required to perform to correct any Defect or Deficiency in the Subcontractors’ or Agent For Contractors’ work. Owner shall be an express third-party beneficiary of all such guarantees and warranties. To the extent available, Owner shall have the right to require Contractor to secure additional warranty or extended guarantee protection pursuant to a Change Order. Upon the earlier of the date of Final Completion or termination of this Agreement, Contractor shall deliver to Owner copies of all relevant contracts providing for such guarantees and warranties.

20.9.2 Upon the earlier of Final Completion or termination of this Agreement, Contractor shall assign to Owner all warranties received by it from Subcontractors that are not otherwise issued in Owner’s name. Such assignment of warranties to Owner must also allow Owner to further assign such warranties. However, in the event that Owner makes any warranty claim against Contractor with respect to any portion of the Work supplied in whole or in part by any Subcontractor, and Contractor fulfills its obligations with respect to such claim by Owner, Contractor shall be entitled to enforce for its own benefit any warranty given by such Subcontractor with respect to such portion of the Work.

 

20.10

NO IMPLIED WARRANTIES.

EXCEPT FOR THE EXPRESS WARRANTIES SET FORTH IN THIS ARTICLE 20 (INCLUDING THE “WARRANTIES”), CONTRACTOR DOES NOT MAKE ANY OTHER WARRANTIES, WHETHER STATUTORY, EXPRESS OR IMPLIED (INCLUDING ANY IMPLIED WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE AND ALL WARRANTIES ARISING FROM COURSE OF DEALING OR USAGE OF TRADE). OWNER’S EXCLUSIVE REMEDIES AND CONTRACTOR’S ONLY OBLIGATIONS ARISING OUT OF OR IN CONNECTION WITH DEFECTIVE WORK (PATENT, LATENT OR OTHERWISE), WHETHER BASED IN CONTRACT, IN TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY), OR OTHERWISE, ARE SET FORTH IN THIS ARTICLE 20. ALL SUCH OTHER WARRANTIES, CONDITIONS AND REPRESENTATIONS ARE HEREBY DISCLAIMED. THE FOREGOING IS NOT INTENDED TO DISCLAIM ANY OTHER OBLIGATIONS OF CONTRACTOR WHICH ARE UNRELATED TO DEFECTS OR DEFICIENCIES IN THE WORK AS EXPRESSLY SET FORTH HEREIN.

 

81


 

20.11

REPAIRS AND TESTING BY OWNER.

20.11.1 During the Warranty Period, without prior notice to Contractor Owner, by itself or through its Affiliate, shall be permitted to (a) make repairs or replacements on the Materials or the Facility and (b) adjust or test the Materials or the Facility as outlined in the operations and maintenance manuals provided by Contractor or any Subcontractor or Agent For Contractor.

20.11.2 In the event of an emergency and if, in the judgment of Owner, the delay that would result from giving prior notice to Contractor could cause serious loss or damage which could be prevented by immediate action, any action (including correction of Defects) may be taken by Owner or a third party chosen by Owner, without giving prior notice to Contractor. In the event such action is taken by Owner, Contractor shall be promptly notified after Corrective Work is implemented, and shall assist whenever and wherever possible in making the necessary corrections. All such warranties obtained shall be in addition to, and shall not alter, the warranties of Contractor. Upon Owner’s request, Contractor shall use all reasonable efforts to force Subcontractors or Agent For Contractors to honor warranties including filing suit to enforce same.

 

20.12

SURVIVAL OF WARRANTIES.

Prior to the end of the Warranty Period, the provisions of this Article 20 shall survive the expiration or earlier termination of this Agreement. The Warranties made herein shall be for the benefit of Owner and its successors and permitted assigns and the respective successors and permitted assigns of any of them, and are fully transferable and assignable. Owner may assign its rights to the Warranties during the Warranty Period to any Affiliate, Lender, or any Person acquiring a substantial ownership interest in the Facility without the consent of Contractor.

 

21.

LIABILITY.

 

21.1

TOTAL LIABILITY CAP.

Notwithstanding anything to the contrary contained herein, Contractor’s cumulative aggregate liability hereunder, whether in contract, warranty (including in respect of Corrective Work), tort, (including negligence whether sole or concurrent), strict liability, products liability, professional liability, indemnity, contribution, statute, at law, in equity, or any other cause of action, shall not exceed an amount equal to [***]; provided that, notwithstanding the foregoing, the limitation of liability set forth in this Section 21.1 shall not: (a) apply in the event of Abandonment of the Project by Contractor; (b) apply to Contractor’s indemnification obligations under this Agreement with respect to: (i) any claims brought by Third Parties (for purposes of this Section 21.1 “Third Parties” shall include Owner’s and its Affiliate’s employees) for bodily injury, death or property damage as described in Section 30.1.2(b); or (ii) costs and expenses incurred by Contractor to fulfill those express indemnity obligations set forth in Sections 5.1.2, 6.4.2, 30.1.1, 30.1.2, 30.1.3 and 40.4.2; (c) apply to Contractor’s obligation to deliver to Owner full legal title to and ownership of all or any portion of the Work as required under this Agreement; (d) include the payment of insurance proceeds

 

 

82


 

under any Project-specific insurance policy obtained by Contractor; (e) include any amount in respect of any Non-Reimbursable Cost; (f) apply in the event of the Gross Negligence or Willful Misconduct of Senior Supervisory Personnel; (g) apply to limit Contractor’s costs incurred to achieve the “make good” obligations under Section 15.3.4; or (h) [***].

 

21.2

NO CONSEQUENTIAL DAMAGES.

Notwithstanding anything to the contrary contained herein, except with respect to (a) any claims for bodily injury, death or physical damage to property of Third Parties for which Contractor owes an indemnity obligation as described in Section 30.1.2(b) (notwithstanding Section 30.1.2(b), with respect to bodily injuries, “Third Parties” shall exclude Owner’s employees for purposes of this Section 21.2), (b) any damages resulting from the Gross Negligence or Willful Misconduct of Senior Supervisory Personnel, (c) any liquidated damages which may be payable as set forth in Article 22, and (d) any damages resulting from Contractor’s breach of Article 27, Contractor, its agents and Affiliates (including the Contractor Guarantors), workers, Subcontractors and suppliers and the employees of each shall not be liable for, and Owner hereby waives, any incidental, indirect, punitive or consequential damages, loss of or default under business contracts, lost revenues or for loss of profit, product, revenue, contract or use arising out of or in connection with the performance of the Work or this Agreement whether or not any such liability is claimed in contract, statute, equity, tort or otherwise and shall apply irrespective of negligence. In addition, except with respect to (a) Third Party claims for which Owner has agreed to indemnify Contractor in accordance with Section 30.2, and (b) Owner’s breach of its confidentiality obligations under Article 27, Owner shall have no liability for, and Contractor hereby waives, releases, defends, indemnifies and holds harmless any incidental, indirect, punitive or consequential damages (which includes loss of or default under business contracts, lost revenues or lost profits but excluding those amounts payable by Owner to Contractor in the event of a termination for default pursuant to Section 31.5 or for convenience pursuant to Article 32) arising out of or in connection with this Agreement.

 

21.3

JOINT AND SEVERAL LIABILITY.

The Parties acknowledge and agree that each Contractor Guarantor shall be jointly and severally liable to Owner for each and every obligation and liability of Contractor under this Agreement, including any liabilities arising out of or relating to the alleged or actual delay, fault, default, non-performance or inadequate performance of Contractor, to the extent provided in each Contractor Guarantee. Without limiting the generality of the foregoing, Owner shall be entitled to make any claim for any damages or liability arising under this Agreement against any or all of the Contractor and the Contractor Guarantors.

 

22.

PERFORMANCE TESTS; LIQUIDATED DAMAGES.

 

22.1

PERFORMANCE TESTS.

The Performance Tests are described in Exhibit R.

 

 

83


 

22.2

SCHEDULE DELAY LIQUIDATED DAMAGES FOR FAILURE TO ACHIEVE LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION OR FACILITY SUBSTANTIAL BY AN APPLICABLE DEADLINE.

22.2.1 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the LPS1 Substantial Completion Date has not occurred on or before the date that is [***] days after the LPS1 Substantial Completion Deadline, Contractor shall:

(a) pay LPS1 Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the LPS1 Substantial Completion Date and (ii) the Day on which Contractor has paid LPS1 Schedule Delay Liquidated Damages in an amount equal to the LPS1 Schedule Delay Liquidated Damages Cap, in the following amounts:

(1) for the period commencing on the date that is [***] days after the LPS1 Substantial Completion Deadline and ending on the date that is [***] days after the LPS1 Substantial Completion Deadline, [***] per day;

( 2 ) for the period commencing on the date that is [***] days after the LPS1 Substantial Completion Deadline and ending on the date that is [***] days after the LPS1 Substantial Completion Deadline, [***] per day;

( 3 ) for the period commencing on the date that is [***] days after the LPS1 Substantial Completion Deadline and ending on the date that is [***] days after the LPS1 Substantial Completion Deadline, [***] per day;

( 4 ) for the period commencing on the date that is [***] days after the LPS1 Substantial Completion Deadline and ending on the date that is [***] days after the LPS1 Substantial Completion Deadline, [***] per day; and

(b) [***]; and

(c) [***]

22.2.2 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the LPS2 Substantial Completion Date has not occurred on or before the date that is [***] days after the LPS2 Substantial Completion Deadline, Contractor shall pay LPS2 Schedule Delay Liquidated Damages to Owner for each and every Day which elapses

 

 

84


 

after such date until the earlier of (i) the LPS2 Substantial Completion Date and (ii) the Day on which Contractor has paid LPS2 Schedule Delay Liquidated Damages in an amount equal to the LPS2 Schedule Delay Liquidated Damages Cap, in the following amounts:

(a) for the period commencing on the date that is [***] days after the LPS2 Substantial Completion Deadline and ending on the date that is [***] days after the LPS2 Substantial Completion Deadline, [***] per day;

(b) for the period commencing on the date that is [***] days after the LPS2 Substantial Completion Deadline and ending on the date that is [***] days after the LPS2 Substantial Completion Deadline, [***] per day;

(c) for the period commencing on the date that is [***] days after the LPS2 Substantial Completion Deadline and ending on the date that is [***] days after the LPS2 Substantial Completion Deadline, [***] per day; and

(d) for the period commencing on the date that is one [***] days after the LPS2 Substantial Completion Deadline and ending on the date that is [***] days after the LPS2 Substantial Completion Deadline, [***] per day.

22.2.3 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the LPS3 Substantial Completion Date has not occurred on or before the date that is [***] days after the LPS3 Substantial Completion Deadline, Contractor shall pay LPS3 Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the LPS3 Substantial Completion Date and (ii) the Day on which Contractor has paid such LPS3 Schedule Delay Liquidated Damages in an amount equal to the LPS3 Schedule Delay Liquidated Damages Cap, in the following amounts:

(a) for the period commencing on the date that is [***] days after the LPS3 Substantial Completion Deadline and ending on the date that is [***] days after the LPS3 Substantial Completion Deadline, [***] per day;

(b) for the period commencing on the date that is [***] days after the LPS3 Substantial Completion Deadline and ending on the date that is [***] days after the LPS3 Substantial Completion Deadline, [***];

(c) for the period commencing on the date that is [***] days after the LPS3 Substantial Completion Deadline and ending on the date that is [***] days after the LPS3 Substantial Completion Deadline, [***] per day; and

(d) for the period commencing on the date that is [***] days after the LPS3 Substantial Completion Deadline and ending on the date that is [***] after the LPS3 Substantial Completion Deadline, [***] per day.

 

85


 

22.2.4 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the LPS4 Substantial Completion Date has not occurred on or before the date that is [***] days after the LPS4 Substantial Completion Deadline, Contractor shall pay LPS4 Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the LPS4 Substantial Completion Date and (ii) the Day on which Contractor has paid such LPS4 Schedule Delay Liquidated Damages in an amount equal to the LPS4 Schedule Delay Liquidated Damages Cap, in the following amounts:

(a) for the period commencing on the date that is [***] days after the LPS4 Substantial Completion Deadline and ending on the date that is [***] days after the LPS4 Substantial Completion Deadline, [***] per day;

(b) for the period commencing on the date that is [***] days after the LPS4 Substantial Completion Deadline and ending on the date that is [***] days after the LPS4 Substantial Completion Deadline, [***];

(c) for the period commencing on the date that is [***] days after the LPS4 Substantial Completion Deadline and ending on the date that is [***] days after the LPS4 Substantial Completion Deadline, [***] per day; and

(d) for the period commencing on the date that is [***] days after the LPS4 Substantial Completion Deadline and ending on the date that is [***] days after the LPS4 Substantial Completion Deadline, [***] per day.

22.2.5 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the Facility Substantial Completion Date has not occurred on or before the date that is [***] days after the Facility Substantial Completion Deadline, Contractor shall pay Facility Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the Facility Substantial Completion Date and (ii) the Day on which Contractor has paid Facility Schedule Delay Liquidated Damages in an amount equal to the Facility Schedule Delay Liquidated Damages Cap, in the following amounts:

(a) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] days after the Facility Substantial Completion Deadline, [***] per day;

(b) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] days after the Facility Substantial Completion Deadline, [***] per day;

 

 

86


 

(c) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] days after the Facility Substantial Completion Deadline, [***] per day; and

(d) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] days after the Facility Substantial Completion Deadline, [***] per day.

22.2.6 Except as set forth in Section 31.2, Contractor’s payment of Schedule Delay Liquidated Damages as set forth in Sections 22.2.1 through 5, and the other remedies set forth in Section 22.2.1(b) and (c), shall be the sole and exclusive remedy of Owner for Contractor’s failure to achieve the LPS1 Substantial Completion Date on or before the LPS1 Substantial Completion Deadline, the LPS2 Substantial Completion Date on or before the LPS2 Substantial Completion Deadline, the LPS3 Substantial Completion Date on or before the LPS3 Substantial Completion Deadline, the LPS4 Substantial Completion Date on or before the LPS4 Substantial Completion Deadline or the Facility Substantial Completion Date on or before the Facility Substantial Completion Deadline.

22.2.7 In the event that the Work fails to achieve any of the requirements provided in this Agreement required to achieve LNG Production System Substantial Completion or Facility Substantial Completion, as evidenced by the Performance Test results, by the LNG Production System Substantial Completion Deadline for an LNG Production System or the Facility Substantial Completion Deadline, as applicable, then LNG Production System Substantial Completion of such LNG Production System or Facility Substantial Completion, as applicable, shall not occur.

 

22.3

LIQUIDATED DAMAGES CAP.

22.3.1 The total amount of Contractor’s obligations to pay Schedule Delay Liquidated Damages pursuant to Section 22.2 shall not exceed the following amounts:

(a) LPS1 Schedule Delay Liquidated Damages shall not exceed [***] (the “LPS1 Schedule Delay Liquidated Damages Cap”);

(b) LPS2 Schedule Delay Liquidated Damages shall not exceed [***] (the “LPS2 Schedule Delay Liquidated Damages Cap”);

(c) LPS3 Schedule Delay Liquidated Damages shall not exceed [***] (the “LPS3 Schedule Delay Liquidated Damages Cap”);

(d) LPS4 Schedule Delay Liquidated Damages shall not exceed [***] (the “LPS4 Schedule Delay Liquidated Damages Cap”); and

(e) Facility Schedule Delay Liquidated Damages shall not exceed [***] (the “Facility Schedule Delay Liquidated Damages Cap”).

 

 

87


 

22.3.2 The total amount of Contractor’s obligations to pay Schedule Delay Liquidated Damages hereunder shall not exceed [***] in the aggregate.

22.3.3 If at any time Contractor is as a result of the operation of Section 22.3.1 or Section 22.3.2 no longer liable hereunder to pay Schedule Delay Liquidated Damages, then Owner may terminate this Agreement in accordance with Sections 31.1.17 and 31.4 or continue to permit Contractor to progress the Work in accordance with the requirements of this Agreement.

 

22.4

PAYMENT.

22.4.1 Schedule Delay Liquidated Damages shall accrue daily hereunder and shall be payable by Contractor monthly, no later than the fifth (5th) Business Day of the immediately following month.

22.4.2 All liquidated damage amounts required to be paid by Contractor under this Article 22 shall cease accruing upon a termination of this Agreement.

 

22.5

LIQUIDATED DAMAGES REASONABLE.

The Parties acknowledge and agree that actual damages for Contractor’s failure to successfully pass the Performance Tests and achieve the relevant milestones by the Applicable Deadlines are difficult to determine and that the liquidated damages set forth herein are reasonable and appropriate measures of the damages for such failure, are apportioned in a fair and appropriate manner including with respect to any lump-sum liquidated damages that may be payable in respect of any single day of delay, and do not represent a penalty. If Contractor, any Contractor Guarantor or anyone on its behalf successfully challenges the applicable rate of any liquidated damages, Contractor specifically agrees to pay Owner all actual damages incurred by Owner in connection with such breach, including any and all consequential damages (such as loss of profits and revenues, business interruption, loss of opportunity and use) and all costs incurred by Owner in proving the same, without regard to any limitations whatsoever set forth herein.

 

22.6

EFFECT ON OTHER PROVISIONS.

The provisions of this Article 22 shall affect neither Contractor’s obligations to complete any other requirement herein which is unrelated to schedule nor Owner’s right to withhold amounts retained under Section 6.8 hereof.

 

23.

SUBCONTRACTORS.

23.1.1 Attached as Exhibit H and Exhibit O is a list of names of potential Major Subcontractors. Contractor may submit to Owner the names and qualifications and recommendations of additional Major Subcontractors that it desires to include in Exhibit H or Exhibit O. Any additions or changes to Exhibit H or Exhibit O shall be decided solely by Owner within a reasonable time following the submission of all necessary supporting documentation by Contractor. At the request of Owner, the Lenders or Owner’s title insurance providers, Contractor shall provide an affidavit of all Major Subcontractors, in a form acceptable to Owner, the Lenders or Owner’s title insurance providers, as applicable. All Major Subcontractors will be selected from

 

 

88


 

Exhibit H or Exhibit O as supplemented from time to time in accordance with this Section 23.1.1. Contractor shall not enter into Major Subcontracts with any Person not listed in Exhibit H or Exhibit O without the prior written approval of Owner. Contractor shall issue all Subcontracts in accordance with the terms of this Agreement. Approval by Owner of any Subcontractor or its receipt or review of any Subcontract shall not (a) relieve Contractor of any of its obligations under this Agreement or (b) constitute any acceptance of the Work undertaken by such Person. No Subcontract shall bind or purport to bind Owner.

23.1.2 Contractor shall include in each Major Subcontract a provision requiring each such Major Subcontractor to comply with and perform for the benefit of Owner all requirements and obligations of Contractor to Owner under this Agreement, to the extent such requirements and obligations are applicable to the performance of the work under the respective Major Subcontract. At a minimum, all Subcontracts shall require the Subcontractors to comply with applicable Laws, Applicable Codes and Standards and Permits, shall provide that Owner has the right of inspection as provided hereunder and require such Subcontractors to (a) be subject to the labor obligations hereunder as well as the safety and security provisions of this Agreement, (b) provide guarantees and warranties with respect to its portion of the Work commensurate with such Major Subcontractor’s work, (c) provide certificates of insurance as set forth herein, (d) grant a license to Owner pursuant to Section 29.2.3, (e) include a termination for convenience provision with terms consistent with the terms set forth herein, and (f) be subject to the confidentiality provisions consistent with the terms set forth herein. Contractor shall use its reasonable efforts to minimize or eliminate cancellation charges or fees in each Subcontract. Additionally, Contractor shall include in each Major Subcontract relating to any Materials or other component of the Facility a requirement that, until the end of the Warranty Period, the Subcontractor shall (i) notify Contractor and Owner in the event Subcontractor intends to discontinue supplying any functional spare parts and (ii) permit Owner to order any quantity of any such parts at the prices prevailing prior to such discontinuance of supply. All Subcontracts must specify that the contractual relationship with the Subcontractor is exclusive to Contractor and that the Subcontractor waives any and all rights to demand any payment directly from Owner.

23.1.3 In addition to the requirements set forth above, Contractor shall include in each Subcontract the following language to make Owner an express third party beneficiary of such Subcontract:

“The parties hereto agree and acknowledge that the services/work/equipment to be provided hereunder by [Subcontractor] will be incorporated into the LNG facility and related facilities being developed by [Owner]. As such, the parties expressly agree that Owner is a third party beneficiary of this [Agreement] entitled, in its own name or in the name of [Contractor], to enforce this [Agreement] against [Subcontractor].”

23.1.4 Contractor shall notify Owner of and coordinate with Owner in connection with the administration of any claim (actual or threatened in writing) arising under any Subcontract or Agent For Contract, and shall request Owner’s approval (such approval not to be unreasonably withheld or delayed) (a) of any external attorney and claims consultant to be appointed by Contractor in connection with such claim and (b) prior to commencing any litigation with respect to such claim. Litigation between Contractor and a Subcontractor or Agent For Contractor shall be jointly managed by Contractor and Owner. Contractor shall not settle any claim arising under a Subcontract or Agent For Contract without Owner’s prior approval.

 

89


 

23.2

CONTRACTOR RESPONSIBLE FOR WORK.

Contractor is responsible for each of the various parts of the Work, so that all items thereof conform in all respects to the requirements of this Agreement, regardless of any failure of any Subcontractor to perform, any disagreement between any Subcontractors, or any disagreement between any Subcontractors, on the one hand, and Contractor or Owner. Contractor shall furnish such information relative to its Subcontractors, including copies of unpriced (and with respect to the Reimbursable Work, all priced) Subcontracts as Owner may reasonably request. Without the express written consent of Owner, nothing contained herein or in any Subcontract awarded by Contractor shall create any contractual relationship between Owner and any Subcontractor. Contractor shall require that all Subcontractors release and waive (to the extent permitted by applicable Law) any and all rights against Owner and the Lenders for recovery of payment of any moneys for compensation for the portion of the Work performed by them.

 

23.3

ASSIGNMENT.

23.3.1 Subject to Section 23.3.2, Contractor hereby assigns to Owner (and Owner’s permitted assigns) all its interest in any Subcontracts (or any portion thereof to the extent such Subcontracts also relate to other projects of Contractor) now existing or hereafter entered into by Contractor for performance of any part of the Work, which assignment will be effective upon acceptance by Owner in writing and only as to those Subcontracts which Owner designates in said writing.

23.3.2 Owner shall not have the right to exercise any right to assignment of any Subcontract pursuant to Section 23.3.1 unless and until (a) any obligation by any Subcontractor under any Subcontract extends beyond the expiration of this Agreement, including the Warranty Period, (b) Owner has elected to terminate this Agreement in accordance with the terms hereof or (c) with respect to the Work, Contractor has failed to perform any of its material obligations or correct Defects and Deficiencies under this Agreement to which such Subcontract relates.

23.3.3 Each Subcontract entered into by Contractor with respect to the Work shall contain a provision permitting its assignment to Owner or the Lenders upon Owner’s written request (following the occurrence of any of the events described in Section 23.3.2).

 

23.4

AGENT FOR CONTRACTS WORK.

Owner has agreed to enter into the Agent For Contracts for the performance of the Agent For Contracts Work and to make timely payment when due of amounts owing under the Agent For Contracts directly to the Agent For Contractors. Owner and Contractor acknowledge and agree that Contractor shall have responsibility, and shall be expressly authorized in the Agent For Contracts, to manage and administer the Agent For Contracts and the Agent For Contracts Work thereunder as part of and with the rights and responsibilities of the Work. Except for Owner’s responsibility to make timely payment when due of amounts owing under the Agent For Contracts directly to the Agent For Contractors, Contractor shall be responsible for the performance or nonperformance for any reason of any Agent For Contractor for any other purposes hereunder as to the Work, including with respect to Defects and Deficiencies.

 

90


 

24.

LABOR RELATIONS.

 

24.1

GENERAL MANAGEMENT OF EMPLOYEES.

Contractor shall exercise its management rights in performing the Work, either specifically detailed in, or not expressly limited by, applicable collective bargaining agreement(s). Subject to Section 5.2, such management rights shall be deemed to include the rights to: hire, discharge, promote and transfer employees; to select and remove foremen or other persons at other levels of supervision; to establish and enforce reasonable standards of productivity; to introduce, to the extent feasible, labor-saving equipment and materials; to determine the number of craftsmen necessary to perform a task, job or other work required with respect to the Facility; and to establish, maintain and enforce rules and regulations conducive to efficient and productive operations.

 

24.2

WAGES AND CONDITIONS.

Contractor shall make its own arrangements for the engagement of all staff and labor, local or otherwise, and for their payment, housing, feeding and transport. Contractor shall pay rates of wages, and observe conditions of labor, not materially different than those established for the trade or industry where the work is carried out, and shall comply with all Laws relating to wages, hours, working conditions and other employer/employee-related matters pertaining to its employees. In addition, Contractor shall certify to the reasonable satisfaction of Owner that all social benefit payments related to the wages of all workers employed directly or indirectly by it and its Subcontractors have been timely paid in full.

 

24.3

VIOLATIONS.

Contractor shall promptly notify Owner of any violations, and the actions to be taken or planned to resolve the violations, of collective bargaining agreements and jurisdictional disputes in connection with the Work including the filing of appropriate processes with any court or administrative agency having jurisdiction to settle, enjoin or award damages resulting from such violations of collective bargaining agreements or jurisdictional disputes.

 

24.4

DISPUTES.

Contractor shall undertake promptly all reasonable efforts to prevent or resolve any strikes or other labor disputes among its employees or the employees of Subcontractors or Agent For Contractors. If a strike or other labor dispute occurs, Contractor shall take all reasonable actions to minimize any resulting disruption of the progress of the Work. Contractor shall advise Owner promptly, in writing, of any actual, anticipated or threatened labor dispute that might affect the performance of the Work by Contractor or by any Subcontractors or Agent For Contractors and will keep Owner informed on a daily basis of the status of the dispute resolution. Notwithstanding the foregoing, the settlement of strikes, walkouts, lockouts or other labor disputes shall be at the sole discretion of the Party having the difficulty. Nothing in this Article 24 shall be deemed to amend the definition of “Force Majeure Event.”

 

 

91


 

24.5

STATUTORY EMPLOYER.

Notwithstanding anything to the contrary contained herein, in all cases where Contractor’s employees (meaning Contractor’s direct, borrowed, special or statutory employees) are covered by the Louisiana Worker’s Compensation Act, La. R.S. 23:1021 et seq., Owner and Contractor agree that Owner shall be and hereby is designated as the statutory employer of Contractor’s direct, borrowed, special and statutory employees, pursuant to La. R.S. 23:1061(A)(3). Owner and Contractor further agree that the Work is an integral part of and essential to Owner’s ability to generate its goods, products and services. This provision is included for the sole purpose of establishing a statutory employer relationship to gain the benefits expressed in La. R.S. 23:1061, and is not intended to create an employer/employee relationship for any other purpose. Nothing contained in this Section 24.5 shall be construed to establish any relationship or status that is inconsistent with Article 37. In the event that Owner is required to pay worker’s compensation benefits to Contractor’s direct, borrowed, special or statutory employees, whether as a statutory employer pursuant to La. R.S. 23:1061 or as a special employer pursuant to La. R.S. 23:1031(C), Owner shall be entitled to reimbursement from Contractor for any such benefit payments. Neither Contractor nor its underwriters shall be entitled to seek contribution from Owner for any worker’s compensation benefits payments made on behalf of any of Contractor’s direct, borrowed, special or statutory employees for purposes of La. R.S. 23:1031(C).

 

24.6

LOCAL LABOR.

Contractor shall use commercially reasonable efforts to attract and retain local labor personnel for the Work and to utilize local Subcontractors whenever possible and cost effective. Contractor agrees to use good faith efforts to award Subcontracts to Subcontractors based in the State of Louisiana and to hire personnel to perform the Work that live in the State of Louisiana.

 

24.7

COMMUNITY IMPACTS.

Contractor shall use reasonable efforts to assist Owner in creating, assessing and carrying out programs which shall, during all phases of the Work, minimize the impacts upon the host community caused by the construction of the Facility. Such programs shall include sequencing of the Work so as to reasonably minimize the impacts of noise and dust at and around the Job Site.

 

25.

TITLE AND RISK OF LOSS.

 

25.1

TRANSFER OF TITLE.

25.1.1 Contractor warrants and guarantees to Owner good and legal title to the Materials and the Work, and shall deliver and convey ownership of the Materials and the Work free and clear of any and all liens, claims, security interest and other encumbrances, when title thereto passes to Owner. Title to all or any portion of the Materials shall pass to Owner upon the earliest of the following:

 

  (a)

the occurrence of any event by which, under applicable Laws, title passes from Contractor or Subcontractors or Agent For Contractors providing such Materials;

 

92


 

  (b)

the date that such Materials are delivered to a shipper for shipment (whether by ship, air, rail, truck or otherwise and whether directly or indirectly) to the Job Site;

 

  (c)

the date that such Materials are delivered to the Job Site; and

 

  (d)

the date of termination of this Agreement, to the extent that Contractor has title.

25.1.2 It is expressly understood and agreed, however, that (a) the passage of title shall not release Contractor from the Contractor’s responsibility to perform fully its obligations hereunder, and (b) in no event shall title to the Owner Furnished Equipment and Materials pass from Owner to Contractor, and Owner shall, at all times, retain title and ownership of the Owner Furnished Equipment and Materials.

 

25.2

RISK OF LOSS.

Notwithstanding passage of title as provided in Section 25.1, Contractor shall bear risk of loss of or damage to the Work and Materials in respect of which Owner has not assumed care, custody and control hereunder until the Facility Substantial Completion Date, but only to the extent (i) of any insurance proceeds actually received by Contractor from claims made under Owner’s Construction and Erection All Risk Insurance Policy or other Owner insurance policies; or (ii) that such loss or damage results from the Gross Negligence or Willful Misconduct of Senior Supervisory Personnel.

 

25.3

PROTECTION OF OWNER.

For the purpose of protecting Owner’s interest in all Materials and Owner Furnished Equipment and Materials delivered to the Job Site with respect to which title has passed to Owner but which remain in the possession of another party, Contractor shall take or cause to be taken all steps necessary under the Laws of the appropriate jurisdiction(s) to protect Owner’s title and to protect Owner against claims by other parties with respect thereto.

 

26.

INSURANCE.

 

26.1

IN GENERAL.

26.1.1 Contractor and Owner shall procure and maintain the insurance enumerated in this Article 26 as being applicable to it. The provisions of this Article 26 do not modify or change or abrogate any responsibility of Owner or Contractor or any Subcontractor or Agent For Contractor stated elsewhere herein. Neither Owner nor Contractor assumes responsibility for the solvency of any insurer or the failure of any insurer to settle any claim. Contractor shall remain responsible for uninsured losses and deductible amounts under the policies to be provided by Contractor and, with respect to losses arising due to Contractor’s or its Subcontractor’s Gross Negligence or Willful Misconduct of Senior Supervisory Personnel, the policies to be provided by Owner until the Facility Substantial Completion Date, and Owner shall become responsible for such losses and deductibles occurring thereafter.

 

93


 

26.1.2 Contractor shall provide the insurance set forth in Section 26.2 with properly licensed insurance carriers and evidence thereof in a form reasonably satisfactory to Owner and the Lenders’ insurance advisors, which insurance carriers shall be (a) rated A- or higher (with a financial size category of at least FSC VII) by A.M. Best’s Key Rating Guide, (b) rated A or higher by Standard and Poor’s or (c) satisfactory to Owner and the Lenders’ insurance advisor, in their sole discretion. Owner shall provide the insurance set forth in Section 26.3 with properly licensed insurance carriers and evidence thereof and that are reinsured with reinsurers that are (i) rated A-or higher (with a financial size category of at least FSC VII) by A.M. Best’s Key Rating Guide or (ii) rated A or higher by Standard and Poor’s. Subject to Section 26.3.1 the Notice to Proceed and any Limited Notice to Proceed shall not be effective until each of Owner and Contractor has provided to each other such satisfactory evidence of insurance. Each Party shall promptly provide written notification to the other Party if it becomes aware of any material change in, non-renewal or cancellation of insurance coverage that such Party is required to maintain hereunder.

26.1.3 All the liability policies (except workers’ compensation, employer’s liability and professional liability) of insurance shall be endorsed to provide a severability of interests or cross liability clause to the benefit of each additional insured.

26.1.4 All Contractor policies of insurance required under this Article 26 shall provide that such insurance shall not be canceled or not renewed without requiring Contractor to give at least [***] Days’ prior Notice to Owner and the Lenders, except with respect to non-payment of premium, in which case such Notice period shall be [***] Days. In addition, all Owner policies of insurance required under this Article 26 shall provide that such insurance shall not be canceled or not renewed without requiring Owner to give at least [***] Days’ prior Notice to Contractor and the Lenders, except with respect to non-payment of premium, in which case such Notice period shall be [***] Days.

26.1.5 If any loss or damage to the Work (on or off the Job Site) is sustained, Contractor shall, at the request of Owner, act on behalf of itself and Owner for the purpose of adjusting the amount of the loss with the insurer. Contractor shall (a) replace or repair any such loss or damage and complete the Work in accordance with this Agreement and (b) take such action as may be reasonable and necessary to mitigate the amount of any such loss. Owner and, at the request of Owner, Contractor shall use commercially reasonable efforts for the benefit of the Parties to pursue all claims for loss or damage to property under the policies required to be provided by Owner pursuant to Section 26.3 that exceed the deductible amounts of such policies. As soon as practicable following a loss event, Contractor, Owner and the assigned loss adjuster shall meet to review the loss or damage and determine the course of action required to remedy the loss or damage. To the extent possible, Contractor and Owner shall determine with the loss adjuster the extent of loss or damage and the level of insurance coverage applicable to such loss or damage. Contractor shall cooperate with and provide the loss adjuster information relevant to the loss or damage, the schedule impact estimates of remediation, and any other reasonable information sought by insurers concerning the loss event. Contractor shall keep Owner reasonably informed of the status of claims negotiations with the insurer for which Contractor is, at the request of Owner, responsible under the Construction and Erection All Risk insurance required to be obtained by Owner pursuant to Section 26.3.1. For the avoidance of doubt, Owner shall remain the sole authority on any decisions related to claims handling, coordination and acceptance of payment on all Owner-procured insurance policies. Advance payments under the applicable insurance policy may be requested of insurers in order to facilitate cash flow and in no event shall Contractor be relieved of its obligation to repair and replace the loss or damage if such advance is not made.

 

94


 

26.1.6 Subject to the requirements and limitations set forth in Sections 26.1.5, (a) Contractor shall include with each Request for Payment any amounts payable by Owner pursuant to this Section 26.1.6 and (b) provided that Contractor comply with all requirements for payment set forth herein, Owner shall pay such amounts in accordance with the terms of this Agreement.

 

26.2

POLICIES TO BE OBTAINED BY CONTRACTOR.

26.2.1 Except for the Construction and Erection All Risk insurance required to be provided by Owner pursuant to Section 26.3.1(a) and Commercial General Liability insurance required to be provided by Owner pursuant to Section 26.3.1(b), Contractor shall obtain and maintain in full force and effect, and shall require, as applicable, Subcontractors to procure and maintain in full force and effect, the following insurance:

(a) General liability insurance written on ISO occurrence form CG 00 01 04/13 covering all activities of Contractor other than the Work at the Job Site, and shall include Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer as additional insureds on a primary and noncontributory basis to the extent of the indemnity obligations assumed by Contractor under this Agreement. Such insurance shall be written in an amount of [***] per occurrence and [***] annual aggregate including a [***] aggregate limit for products and completed operations. Such insurance shall be endorsed to include coverage for products and completed operations for ten (10) years after the Facility Substantial Completion Date or the statute of repose, whichever is less. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed by Contractor under this Agreement;

(b) Workers Compensation, and if applicable, United Longshore and Harbor Workers Compensation Act insurance and Jones Act coverage, or similar insurance in the form prescribed by relevant laws and insuring against work related losses and claims arising in connection with the performance of the Work by Contractor. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed under this Agreement by Contractor;

(c) Employer’s Liability with limits available under a primary or excess policy equal to the equivalent of [***] per accident/occurrence or such higher limit as may be required by Laws. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed under this Agreement by Contractor;

 

95


 

(d) Automobile Liability Insurance applicable to all owned, non-owned, hired and leased automotive equipment used in the performance of the Work, including contractual liability, with limits of [***] per accident/occurrence combined single limit including Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer as additional insureds on a primary and noncontributory basis to the extent of the indemnity obligations assumed under this Agreement by Contractor. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed under this Agreement by Contractor;

(e) Umbrella/Excess Liability Insurance providing coverage over the underlying insurance required in Sections 26.2.1(a), 26.2.1(c), and 26.2.1(d) with limits of [***] per occurrence and in the annual aggregate. Such insurance shall include Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer as additional insureds on a primary and noncontributory basis, and include a waiver of subrogation in favor of such additional insureds to the extent of the indemnity obligations assumed by Contractor under this Agreement;

(f) Contractor shall maintain or require to be maintained Professional Liability Insurance, on account of any errors or omissions of Contractor and Subcontractors involved in Work contracted hereunder with liability limits of insurance of [***] per claim and [***] in the aggregate during construction and for a five (5) year period after Final Completion;

(g) Contractor shall either (i) maintain or require to be maintained project specific Pollution Liability Insurance, for any event caused or exacerbated by actions or inactions of Contractor and Subcontractors involved in Work contracted hereunder with liability limits of insurance of at least [***] per occurrence and [***] in the annual aggregate during construction and include Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer as additional insureds on a primary and non-contributory basis, and include a waiver of subrogation in favor of such additional insureds, or (ii) provide Owner and the Lenders with such security as is deemed sufficient by such parties to cover any such errors and omissions; and

(h) For all vessels owned, operated, chartered, or brokered by or for Contractor or any of the Subcontractors in connection with the Work, Contractor shall carry or require the owner or operator of such vessels to carry watercraft insurance, as follows: (i) Hull Insurance for full fair value; (ii) Protection and Indemnity Insurance under Form SP-23 (Revised 1/56), or most

 

96


 

recent version, to cover liabilities arising out of the ownership, operation and use of any vessel with liability limits of insurance of [***] per occurrence, including (y) pollution and environmental liability insurance upon such vessels for damages, cleanup and restoration costs, in amount no less than those limits required by applicable Law and coverage for crew and personnel on such vessels, with no exclusion for activities arising from the use of remote operated vehicles and submarines and diving operations (if these operations are to be performed under this Agreement), and (z) including collision and tower’s liability, cargo legal liability (to the extent applicable), and coverage for liabilities for the removal of wreck or debris as compulsory under statute or as requested by applicable Government Authorities. Insurers shall waive any right to limit liability to the value of the vessel, but only with respect to Owner indemnified parties, whichever is applicable, and the phrase “as owner of vessel named herein” and all similar phrases purporting to limit the insurer’s liability to that of an owner shall be deleted. The coverage in clause (y) regarding pollution and environmental liability insurance for damages, cleanup and restoration costs (in amount no less than those limits required by applicable Law) may be provided under a marine pollution liability policy; provided that such policy provides the same coverage and limits that would be provided under the protection and indemnity insurance. Should the Work necessitate the use of remotely operated vehicles or dredging, this protection and indemnity insurance shall include a specialist operation endorsement; and (iii) Charterer’s Legal Liability Insurance to cover liabilities arising out of operation and use of any time or voyage chartered vessel including coverage for contractual liability for those liabilities assumed by Contractor herein with liability limits of insurance of [***] per occurrence. The insurance listed in clauses (y) and (z) above shall provide that seaworthiness of vessels used to perform Work hereunder is accepted by insurers (or that insurers shall waive in favor of Owner indemnified parties, the vessel owner’s and/or Contractor’s warranty of seaworthiness).

26.2.2 Each policy described under this Section 26.2 shall contain terms and conditions reasonably acceptable to Owner and the Lenders and shall be issued by insurers reasonably acceptable to Owner, and Contractor shall forward to Owner certificates evidencing the coverage is in effect.

26.2.3 Contractor shall be responsible for additional costs associated with modifying any inadequate coverage, terms and conditions to meet the requirements of this Section 26.2. Contractor shall comply with all the conditions and requirements provided for in its insurance policies and to the extent Contractor has been notified in writing of such conditions and requirements the policies required to be maintained by Owner pursuant to Section 26.3. Contractor shall make no material adverse alteration to the terms of any insurance required herein without the prior written approval of Owner and the Independent Engineer. If an insurer makes (or purports to make) any such alteration, Contractor shall notify Owner immediately.

26.2.4 Contractor shall require all insurers under Contractor’s insurance policies to provide Owner and such other interested Persons as may be designated by Owner with certificates of insurance, in form and substance reasonably acceptable to Owner, evidencing and describing the insurance policies and endorsements maintained hereunder prior to commencement of the Work, or upon issuance of such policies, if earlier, and prior to each issuance anniversary date throughout the term of this Agreement. The certificates of insurance shall evidence and describe the insurance policies and endorsements. Notwithstanding anything to the contrary contained herein, evidence of such coverage shall be provided to Owner as a condition precedent to the commencement of the Work.

 

97


 

26.2.5 In respect of all of the Contractor’s insurance policies, Contractor shall, on or before the Notice to Proceed Date and as may be requested by Owner from time to time, produce the Contractor’s certificates of insurance, and required endorsements. If policies have been secured on a project specific basis, Contractor shall provide the actual policy upon written request by Owner.

26.2.6 Before permitting any of its Subcontractors to perform any Work at the Job Site, Contractor shall obtain a certificate of insurance from each such Subcontractor evidencing that such Subcontractor has obtained the insurance required of Subcontractors by Contractor, such insurance at a minimum to include Workers Compensation, and if applicable, United Longshore and Harbor Workers Compensation Act insurance and Jones Act coverage, general liability, employer’s liability and umbrella/excess liability insurance and, with respect to Subcontractors that charter a vessel for the purpose of their work, the insurance described in Section 26.2.1(h). Policies provided by Subcontractors shall be in amounts and upon conditions as are customarily and normally provided for work similar to the Work. Contractor shall use reasonable efforts to cause all Major Subcontractors to include in their respective insurance policies a waiver of any right of subrogation of the insurers thereunder against Owner, the Lenders, the Independent Engineer and Contractor, and any right of the insurers to set off or counterclaim, offset or any other deduction, whether by attachment or otherwise, in respect of any liability of any such Person insured under such policy.

26.2.7 If Contractor shall fail to obtain and keep in force insurance required pursuant to this Section 26.2, Owner may, without limiting any other remedy it may have, obtain and keep in force any such insurance and pay such premium or premiums as may be necessary for that purpose and recover from Contractor whether by way of deduction, offset or otherwise the cost of obtaining and maintaining such insurance.

26.2.8 Except as directed by Owner, Contractor shall be responsible for managing and administering all of Contractor’s insurance policies, including the payment of all deductibles pursuant to Section 26.1.1 and self-insured retention amounts, the filing of all claims and the taking of all necessary and proper steps to collect any proceeds on behalf of the relevant insured Person. Contractor shall at all times keep Owner informed of the filing and progress of any claim arising out of or relating to the Work. If Contractor shall fail to perform these responsibilities, upon reasonable written notice Owner may take such action as it determines appropriate under the circumstances. In the event Contractor collects proceeds on behalf of other Persons, it shall ensure that these are paid directly from the insurers to the relevant Person and, in the event that it receives any such proceeds, it shall, unless otherwise directed by Owner, pay such proceed to such Party forthwith and prior thereto, hold the same in trust for the recipient.

26.2.9 All equipment, tools, supplies and materials belonging to Contractor or any Subcontractor and used by Contractor or such Subcontractor for the performance of the Work and not to be incorporated into or to be left at the Facility shall be brought to and kept at the Job Site at the cost and risk of Contractor or such Subcontractor, and Owner shall not be liable for loss or damage thereto and any insurance policies carried by Contractor or Subcontractors shall waive the

 

98


 

insurer’s right to subrogation against Owner, the Lenders and the Independent Engineer, and their respective assignees, subsidiaries, Affiliates and employees. Contractor shall obtain, or shall cause Subcontractors to obtain, adequate insurance to cover any construction tools and equipment leased from Third Parties.

 

26.3

POLICIES TO BE OBTAINED BY OWNER.

26.3.1 From and after the earlier of the Notice to Proceed Date and such other date as the Parties may mutually agree upon in writing (whether earlier or later) through Final Completion, Owner shall obtain and maintain in full force and effect at its cost, the following insurance with respect to the procurement, construction, erection, Pre-Commissioning, Commissioning, testing and pre-completion operation of the Materials, the Work at the Job Site and the Facility; provided that Owner shall not be obligated to obtain Construction and Erection All Risk insurance before the date upon which Contractor or any Subcontractor will begin Work at, or deliver Materials to, the Job Site:

(a) Construction and Erection All Risk insurance (excluding Contractor’s and Subcontractors’ equipment and property not intended to be installed into the Facility). Such insurance policy shall be written on a replacement cost basis and be in the joint names of Owner and the Lenders as named insureds and Contractor and Subcontractors as additional insureds with a waiver of the insurer’s rights of subrogation in favor of all such named insureds and additional insureds. The deductible under such insurance shall be consistent with the terms reasonably and commercially available in the insurance marketplace considering the equipment and maturity of its design and location. The policy shall also provide, in amounts reasonably acceptable to the Lenders, (i) coverage for removal of debris, (ii) transit coverage with worldwide coverage territory including the continental boundaries of the United States of America and intracoastal waterways adjacent thereto, not including air and ocean marine coverage, (iii) off-site storage coverage, (iv) pollution clean-up and removal (with per occurrence and policy aggregate sublimits), (v) professional fees, (vi) operational and performance testing, (vii) earth movement, flood, named windstorm, expediting expense (with per occurrence and policy aggregate sublimits), (viii) minimization of loss expense, (ix) design defect clause no more restrictive than LEG 2/96, (x) 50/50 hidden damage clause, (xi) advance payment clause and (xii) fire department charges clause. The deductible under such insurance shall be for Owner’s account. Owner may, in its sole discretion, carry and maintain Delay in Commissioning or Start-up insurance covering at least Owner’s debt service payments (principal and interest), and as the Lenders may require, continuous fixed expenses and additional expenses incurred as a result of loss or damage covered under the insurance provided pursuant to Sections 26.3.1(a) and 26.3.1(c). Any recovery under the Delay in Commissioning or Start-up coverage will accrue to the benefit of Owner. If an event or events occur that may be covered by the Delay in Commissioning or Start-up insurance, it shall be Owner’s sole option to decide whether to file a claim under such Delay in Commissioning or Start-up insurance.

(b) Owner Controlled Insurance Program for Commercial General Liability insurance with a limit of at least [***] per occurrence and in the aggregate for bodily injury and property damage at the Job Site. Such coverage shall name Owner, the Lenders, Contractor and Subcontractor as insureds with a waiver of subrogation in favor of any insured and shall include a severability of interest and cross liability provision.

 

99


 

Coverage may be arranged in combination of primary and excess coverage. The deductible shall be for Owner’s account. Owner’s procurement and provision of this insurance shall in no way relieve Contractor or any Subcontractor of any responsibility or liability under this Agreement, any applicable law, statute, regulation or order.

(c) Subject to prevailing terms in the insurance marketplace, air and ocean cargo coverage for all Materials shipped to the Job Site (other than locally procured Materials) and insuring the interest of Owner, the Lenders, Contractor and Subcontractors written on a warehouse to final destination basis from customary “all risk” air and marine perils while in transit. Such policy shall be written on replacement cost basis or in such other amounts acceptable to Owner, the Lenders and Contractor, and shall be subject to a per conveyance limit equivalent to the maximum value of the shipment. The deductibles under such insurance shall be for Owner’s account. Contractor shall provide Owner with schedules and Notices of air and marine shipments pursuant to Section 3.8.18. Owner shall be responsible for any required load survey costs incurred in connection with any shipment of Materials or equipment for Work performed under this Agreement.

(d) Upon the LNG Production System Substantial Completion of each LNG Production System, Owner shall have in place a Commercial Property Policy for such LNG Production System and corresponding LNG Production System Handover Package from the time care, custody and control of such LNG Production System Handover Package transfers from Contractor to Owner in accordance with Section 18.1.3. Such policy shall contain a waiver of subrogation in favor of Contractor and its Subcontractors.

26.3.2 Owner shall also provide Contractor with satisfactory evidence of the existence of insurance policies obtained by Owner prior to an effective Notice to Proceed Date and copies of the policies of insurance obtained by Owner not later than thirty (30) days following the Notice to Proceed Date.

26.3.3 Insurance required to be maintained by Owner hereunder shall be subject to standard sublimits and exclusions available in the insurance marketplace.

26.3.4 All insurance referred to in this or any other Section of this Agreement shall be subject to review and acceptance by the Lenders, and Contractor shall assist as necessary in arranging and maintaining all such insurance and shall not do or omit to do anything that may cause such policy to be invalidated or a valid claim to be repudiated.

26.3.5 Each of Owner and Contractor shall also purchase insurance that may be statutorily required from time to time and/or enroll employees in such state schemes as may be so required at each Party’s own expense during the term of this Agreement.

26.3.6 Contractor shall cooperate with Owner and its insurers to provide any information requested by the insurers necessary to obtain such extension to the insurance policies.

 

100


 

27.

CONFIDENTIAL TREATMENT OF PROPRIETARY INFORMATION; RELIANCE ON INFORMATION.

 

27.1

CONFIDENTIAL TREATMENT.

27.1.1 Contractor covenants and warrants (on behalf of its Representatives) that it shall not (without in each instance obtaining Owner’s prior written consent) disclose, make commercial or other use of, or give or sell to any Person any non-public information regarding Owner, its Affiliates or the Facility (including commercially sensitive information related to the transactions contemplated hereby) (“Confidential Information”); provided, however, that Contractor may disclose such Confidential Information (but only to the extent necessary) (a) to its Representatives, Subcontractors and suppliers who have a need to know such Confidential Information, (b) to its counsel, (c) to any Government Authority to the extent required by Law to be disclosed, (d) under seal in connection with any arbitration, mediation or litigation or (e) to the Lenders or the Independent Engineer in connection with the Financing or insurance underwriters in connection with the Work; provided, further, that any Confidential Information disclosed pursuant to clauses (a), (b), (d) and (e) shall not be disclosed unless (i) the recipient is informed as to the confidential nature of such information, (ii) the recipient agrees to a separate confidentiality agreement with terms and conditions as least as restrictive as this Section 27.1.1 as a condition to the receipt of such Confidential Information and (iii) the disclosing Party remains liable for any breach of this Section 27.1.1 if the breach is caused by the disclosing party or its officers or employees; provided, further, that prior to any disclosure of Confidential Information pursuant to clause (c), Contractor shall give reasonable notice to Owner of the information required to be disclosed and, to the extent reasonably capable under applicable Law and the circumstances surrounding the disclosure, shall provide Owner with an opportunity to take appropriate steps Owner believes are necessary to protect the confidentiality and/or proprietary nature of its Confidential Information. Contractor shall not, nor shall it permit any of its subsidiaries or Affiliates to, issue or cause the publication of any press release or other public statements, announcements or disclosure with respect to this Agreement or the transactions contemplated hereby, or otherwise use Owner’s trademarks, service marks, trade names, logos, domain names, or other indicia of source, association, or sponsorship, without the written consent of Owner. The duration of the obligations stated in this Section 27.1 shall be (x) for Confidential Information that is identified by Owner to be a trade secret, for so long as such Confidential Information remains confidential, and (y) for all other Confidential Information, for a period of [***] years after the expiration or termination of this Agreement. Information shall not be deemed to be “Confidential Information” where: (A) it is or becomes public information or otherwise generally available to the public through no act of or failure to act by Contractor; (B) it was, prior to the Effective Date, already in the possession of Contractor and was not received by Contractor directly or indirectly from Owner and is not subject to a confidentiality agreement; (C) it is rightfully received by Contractor from a third party who is not prohibited from disclosing it to Contractor and is not breaching any agreement by disclosing it to Contractor; or (D) was independently developed by the Contractor without the use of any Confidential Information of Owner. Specific information shall not be deemed to be within the exceptions of the previous sentence merely because it is embraced by more general information within such exceptions, nor shall a combination of features be deemed to be within such exceptions merely because the individual features are within such exceptions. Contractor acknowledges that in the event of a breach of any of the terms contained in this Article 27, Owner may suffer irreparable harm for which remedies at law, including damages, would be inadequate, and that Owner shall be entitled to seek equitable relief therefor by injunction, in addition to any and all rights and remedies available to it at law and in equity, without the requirement of posting a bond.

 

 

101


 

27.1.2 Without limiting Section 27.1.3, Owner covenants and warrants (on behalf of its Representatives and the Independent Engineer ) that it shall not (without in each instance obtaining Contractor’s prior written consent) disclose, make commercial or give or sell to any Person any non-public information regarding the Contractor’s reimbursable or unit rates, the liability and liquidated damages caps set forth in this Agreement, Contractor Intellectual Property, or other commercial information of Contractor unrelated to the Facility, the Work, this Agreement and not required to be provided or licensed to Owner under Article 29 (collectively, “Contractor Confidential Information”); provided, however, that Owner may disclose the Contractor Confidential Information listed in (i) above (but only to the extent necessary) to the parties listed in Section 27.1.1 (a) through (e) above, applied on a mutatis mutandis basis, and Owner’s existing or potential LNG offtakers and buyers, and so long as the recipient agrees to maintain the confidentiality of Contractor Confidential Information on terms and conditions as least as restrictive as those set forth herein; and provided, further, that, except as necessary for Owner to invoice any Owner Contractor for corrective or remedial work performed by Contractor, Owner shall not directly or indirectly provide the Contractor Confidential Information to any engineering, construction and procurement contractor (including UOP, BH and CB&I) that provides engineering, construction and procurement services for chemical or LNG facilities as a substantial part of its business without the prior written consent of the Contractor. Section 27.1.2 shall apply on a mutatis mutandis basis to Contractor Confidential Information. Owner acknowledges that in the event of a breach of any of the terms contained in this Article 27, Contractor may suffer irreparable harm for which remedies at law, including damages, would be inadequate, and that Contractor shall be entitled to seek equitable relief therefor by injunction, in addition to any and all rights and remedies available to it at law and in equity, without the requirement of posting a bond. Information shall not be deemed to be “Contractor Confidential Information” where: (A) it is or becomes public information or otherwise generally available to the public through no act of or failure to act by Owner; (B) it was, prior to the Effective Date, already in the possession of Owner and was not received by Owner directly or indirectly from Contractor and is not subject to a confidentiality agreement; (C) it is rightfully received by Owner from a third party who is not prohibited from disclosing it to Owner and is not breaching any agreement by disclosing it to Owner; or (D) was independently developed by Owner without the use of any Contractor Confidential Information. Specific information shall not be deemed to be within the exceptions of the previous sentence merely because it is embraced by more general information within such exceptions, nor shall a combination of features be deemed to be within such exceptions merely because the individual features are within such exceptions.

27.1.3 All right and title to, and interest in, the Confidential Information shall remain with Owner. All Confidential Information obtained, developed or created by or for Contractor exclusively for the Facility, including copies thereof, is and shall be the sole and exclusive property of Owner (except Contractor Intellectual Property contained therein, which will be governed by Section 0), whether delivered to Owner or not, and Contractor agrees to assign and hereby assigns any and all right, title, and interest therein it may have to Owner, in each case subject to Section 29.1. No right or license is granted to Contractor or any third party respecting the use of Confidential Information by virtue of this Agreement, except to the limited extent required for the Contractor’s performance of its obligations hereunder. Contractor shall cease all use of and deliver

 

102


 

to Owner or destroy all Confidential Information, including all copies thereof, upon Owner’s request, provided Contractor may retain a copy of the Confidential Information to comply with applicable Law, and to the extent any routine computer back-up procedures create copies in the associated back-up or archival computer storage system. Such copies retained shall remain subject to the provisions of this Agreement.

 

27.2

RELIANCE ON INFORMATION.

Subject to Article 29, Owner shall have unrestricted use of Drawings and Specifications provided to Owner pursuant to this Agreement. Owner shall defend, indemnify, and hold the Contractor Indemnitees harmless from and against any use by Owner, its Affiliates, other contractors, representatives, or agents of the Drawings and Specifications for any purpose other than for the Facility.

 

28.

REPRESENTATIONS AND WARRANTIES.

 

28.1

OWNER REPRESENTATIONS AND WARRANTIES.

Owner represents and warrants that as of the Second Restatement Date:

28.1.1 Owner is a limited liability company duly organized and validly existing in good standing under the laws of the State of Delaware and has all necessary power and authority to enter into and perform its obligations under this Agreement;

28.1.2 Each of the execution, delivery and performance by Owner of this Agreement has been duly authorized by all necessary action on the part of Owner and does not contravene or constitute a default under any provision of applicable Law, the constituting documents or the certificate of formation of Owner or of any other agreement, judgment, injunction, order, decree or other instrument binding upon Owner;

28.1.3 Owner has duly executed and delivered this Agreement and, assuming the due authorization, execution and delivery thereof by Contractor, this Agreement constitutes (or when so executed and delivered will constitute) a valid and binding obligation of Owner enforceable against Owner in accordance with its terms, except that (a) such enforceability may be limited by applicable bankruptcy, insolvency, reorganization, liquidation, moratorium or similar laws affecting creditors’ rights generally and (b) the application of general equitable principles may limit the availability of certain remedies; and

28.1.4 There is no pending action, suit, proceeding, inquiry or investigation against it, at law or in equity or before or by any Government Authority, of which it has received notice, or which it has knowledge is threatened which would materially and adversely affect its ability to perform its obligations under this Agreement. It is not in violation of any Law which, individually or in the aggregate, would affect its performance of any obligations under this Agreement.

 

28.2

CONTRACTOR REPRESENTATIONS AND WARRANTIES.

Contractor represents and warrants that as of the Second Restatement Date:

 

 

103


 

28.2.1 It is a limited liability company duly organized and validly existing in good standing under the laws of the State of Texas, is wholly-owned, collectively, by the JV Members, and has all necessary power and authority to carry on its business as presently conducted, to own or hold under lease its properties and to enter into and perform its obligations under this Agreement;

28.2.2 Each of the execution, delivery and performance by it of this Agreement has been duly authorized by all necessary action on its part, does not require any approval, except as has been heretofore obtained, of its board of directors or shareholders or any consent of or approval from any trustee, lessor or holder of any indebtedness or other obligation of it, except for such as have been duly obtained, and does not contravene or constitute a default under any provision of applicable Law, its constituting documents (including the JV Agreement) or by-laws or of any agreement, judgment, injunction, order, decree or other instrument binding upon it, or subject the Facility or any component part thereof or the Job Site or any portion thereof to any lien other than as contemplated or permitted by this Agreement; and it is in compliance with all applicable Laws (a) which govern its ability to perform its obligations under this Agreement or (b) the noncompliance with which would have a material adverse effect on it;

28.2.3 Neither the execution and delivery by it of this Agreement, nor the consummation by it of any of the transactions contemplated hereby, requires the consent or approval of, the giving of notice to, the registration with, the recording or filing of any document with, or the taking of any other action in respect of any Government Authority, except such as are not yet required, and it has no reason to believe that the same will not be readily obtainable in the ordinary course of business upon due application therefor, or which have been duly obtained and are in full force and effect;

28.2.4 It has duly executed and delivered this Agreement, and, assuming the due authorization, execution and delivery thereof by Owner, this Agreement constitutes (or when so executed and delivered will constitute) its valid and binding obligation, enforceable against it in accordance with its terms, except that (a) such enforceability may be limited by applicable bankruptcy, insolvency, reorganization, liquidation, moratorium or similar laws affecting creditors’ rights generally and (b) the application of general equitable principles may limit the availability of certain remedies;

28.2.5 Contractor has substantial experience and all the required skills and capacity necessary for the engineering, procurement and fabrication of Materials used in LNG export and liquefaction facilities comparable to the Facility, and is fully qualified to engineer, procure and construct the Work and otherwise perform the Work in accordance with this Agreement;

28.2.6 It understands that as background information and as an accommodation to it, prior to the Effective Date Owner may provide or may have provided it with copies of certain studies, reports or other information. It further acknowledges and agrees that (a) Owner makes no representations or warranties with respect to the accuracy of such documents or the information or opinions therein contained or expressed unless expressly stated herein (including any Exhibit hereto), (b) Owner shall not be liable to it in contract, tort or otherwise as a result of the use of such information by it, except as expressly provided herein and (c) except for the Relied Upon Information, it shall not rely upon such information without satisfying itself as to its accuracy and completeness;

 

104


 

28.2.7 It (a) has examined this Agreement, including all Exhibits attached hereto, thoroughly and become familiar with all its terms and provisions and to the best of its knowledge, it has reviewed all other documents and information necessary and available to it in order to ascertain the nature, location and scope of the Work, the character and accessibility of the Job Site and surrounding area, the existence of obstacles at the Job Site and surrounding area to the performance of the Work, the availability of facilities and utilities, and the location and character of any existing or adjacent work or structures, and based on such examination and review has no reason to believe that it will be unable to complete the Work in accordance with this Agreement and (b) expressly waives any claims for additional compensation, reimbursement, damages, liabilities or time extension in connection with such conditions, except as otherwise provided herein including Sections 3.3 and 12.4;

28.2.8 There is no pending action, suit, proceeding, inquiry or investigation against it, at law or in equity or before or by any Government Authority, of which it has received notice, or which it has knowledge is threatened which would materially and adversely affect its ability to perform its obligations under this Agreement. It is not in violation of any Law which, individually or in the aggregate, would affect its performance of any obligations under this Agreement;

28.2.9 The terms and conditions of the JV Agreement are substantially consistent with the terms and conditions described in that certain Memorandum of Understanding between the JV Members that was disclosed to Owner prior to the First Restatement Date and do not materially impair the ability of the Contractor to perform any of its obligations under this Agreement; and

28.2.10 None of the Inventions, Materials or the design, engineering and other Work or services rendered by it hereunder, nor the use or ownership thereof by Owner, infringes, as of the Effective Date or prior to Final Completion violates or constitutes a misappropriation of any third party Intellectual Property rights (including any trade secrets, proprietary rights, patents, or copyrights) or trademark, and Contractor further has all requisite rights to grant Owner such rights specified in Article 29.

 

29.

INTELLECTUAL PROPERTY AND LICENSES.

 

29.1

OWNERSHIP.

Contractor shall disclose promptly in writing to Owner all inventions, discoveries, developments and other Intellectual Property which it or its employees or agents (a) may make, create, develop, invent, conceive or first reduce to practice which are based on or derived from Confidential Information or other proprietary information received from Owner or (b) made, created, developed, invented, conceived or first reduced to practice hereunder for the purposes of the Work (but excluding Contractor Intellectual Property) ((a) and (b) collectively, “Inventions”). All right, title and interest (including all Intellectual Property rights other than Contractor Intellectual Property) in and to all such Inventions, as well as any Deliverables (including all Intellectual Property rights therein other than Contractor Intellectual Property) provided hereunder, shall be the sole and exclusive property of Owner, and Contractor agrees to assign and hereby

 

 

105


 

assigns all such right, title, and interest in and to all such Inventions and Deliverables (including all Intellectual Property rights therein other than to Contractor Intellectual Property) to Owner. Contractor retains all right, title and interest to all Contractor Intellectual Property. Nothing in this Agreement grants to Contractor any right under or to Owner’s Intellectual Property.

 

29.2

LICENSES.

29.2.1 From the receipt of the first payment on or following the Notice to Proceed Date, Contractor hereby grants to Owner and its Affiliates (and shall procure for Owner from any Subcontractors) a perpetual, irrevocable (so long as Owner has not been finally adjudged by court or arbitral tribunal to be in material breach of its payment obligations hereunder), royalty-free, transferable (limited to its Affiliates, any Lender exercising any step-in rights or any owner of the Facility), worldwide, nonexclusive license in, to, and under the Contractor Intellectual Property to copy, modify, reproduce, distribute, practice, and otherwise utilize the same to the extent reasonably necessary for the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, reconstruction, alteration or modification of the Facility (including any portion, subsystem, unit or component thereof), but not including the right to grant sublicenses to third parties except in connection with and as necessary for the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem, unit or component thereof) or to accomplish an above-permitted transfer.

29.2.2 Contractor agrees to execute or have executed all documents, and to perform or have performed all lawful acts that Owner may deem reasonably desirable or necessary to perfect its (or its designee’s) ownership of or license(s) to which it is entitled pursuant to this Article 29.

29.2.3 Contractor shall, prior to directing any Subcontractors or Agent For Contractor to perform any part of the Work, obtain a valid written assignment and license from each such Subcontractor or Agent For Contractor covering the same items and on identical (or if identical terms cannot be obtained, despite Contractor’s commercial reasonably efforts to do so and so long as prior written notice is provided to Owner, equivalent) terms as those that obligate Contractor to the Owner as expressed in this Article 29.

 

29.3

DATA.

Subject to the retention by Contractor of all Contractor Intellectual Property, all Drawings and Specifications furnished or required to be furnished by Contractor to Owner in performing the Work (including all Intellectual Property rights therein) are and shall be the sole and exclusive property of Owner, and Contractor agrees to assign and hereby assigns all such right, title and interest in and to all such Drawings and Specifications (including all Intellectual Property rights therein, but excluding Contractor Intellectual Property) to Owner. From the First Restatement Date, Contractor grants to Owner, without limitation of Section 29.2.1, a perpetual, irrevocable (so long as Owner has not been finally adjudged by court or arbitral tribunal to be in material breach of its payment obligations hereunder), worldwide, nonexclusive, nontransferable (except to Owner’s Affiliates, any Lender exercising step-in rights or any owner of the Facility), royalty-free right to use all Intellectual Property included in the Drawings and Specifications (including technical information and software), that is not owned by Owner, all for the purpose of the

 

106


 

completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (including any portion, subsystem, unit or component thereof), but not including the right to grant sublicense to third parties except in connection with and as necessary for the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem, unit or component thereof) or to accomplish an above-permitted transfer.

 

30.

INDEMNIFICATION.

 

30.1

CONTRACTOR INDEMNITY.

30.1.1 Contractor shall defend, indemnify, and hold the Owner Indemnitees harmless from and against any and all Losses incurred by any such Owner Indemnitees to the extent arising from or based on any Intellectual Property Claim. If any use, operation, or enjoyment of the Facility or any part thereof is the subject of an Intellectual Property Claim, then, in addition, Contractor shall promptly, but in no event later than thirty (30) days from the date of notice from Owner, commence action to remove such impediment, and thereafter shall diligently pursue removal of such impediment, (at Contractor’s option) by: (a) procuring for Owner, or reimbursing Owner for procuring, the right to continue using the subject of the Intellectual Property Claim; (b) modifying the subject of the Intellectual Property Claim to avoid the alleged infringement, disclosure, use, misappropriation or other violation, while maintaining substantially the same performance, quality and expected life satisfying the requirements of this Agreement, to the reasonable satisfaction of Owner; or (c) replacing the subject of the Intellectual Property Claim with service, Materials, Inventions, or other Work or Contractor Intellectual Property, as applicable, of comparable functionality and quality and satisfying the requirements of this Agreement, to the reasonable satisfaction of Owner, that avoids the alleged infringement, disclosure, use, misappropriation or other violation; provided that in no case shall Contractor take any action which materially and adversely affects Owner’s continued completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem or component thereof) without the prior written consent of Owner; and provided further, that in no event shall Contractor have such indemnity obligations or obligation to remove such impediment for any Intellectual Property Claim arising from or in connection with (i) the Owner Furnished Equipment and Materials or any written instruction, written information, designs, specifications, or other materials provided by Owner to Contractor, (ii) any action or omission of any Owner Contractor, or (iii) any modification of the Work directed by Owner or that was not authorized by Contractor. For the avoidance of doubt, Owner’s acceptance of the Materials, Deliverables, Inventions, and other equipment or any other component of the Work shall not be construed to relieve Contractor of any obligation hereunder. Owner shall, and shall cause other Owner Indemnitees to, agree to reasonably cooperate and assist Contractor in the defense of any Intellectual Property Claims, at Contractor’s cost. Any Owner Indemnitee that seeks to settle any Intellectual Property Claim shall seek the prior approval of Contractor, which approval shall not be unreasonably withheld, conditioned, or delayed, in respect of such settlement. Contractor shall not settle any Intellectual Property Claim that includes any non-monetary obligations without the prior approval of Owner, which approval shall not be unreasonably withheld, conditioned, or delayed, in respect of such settlement.

 

107


 

30.1.2 In addition to its indemnification, defense and hold harmless obligations contained elsewhere herein, to the fullest extent permitted by Law, Contractor assumes liability for, and agrees to indemnify, protect, save and hold harmless and defend each of the Owner Indemnitees from and against any and all Losses (including any strict liability, all fines and penalties as well as reasonable attorneys’ fees, consultant fees, experts’ fees and litigation expenses) of whatsoever kind and nature that may be imposed on, suffered or incurred by or asserted against any Owner Indemnitee in any way relating to or directly or indirectly arising out of (a) the presence, Release or threatened Release of any Hazardous Substance used, generated or handled by or brought to the Job Site or disposed by or at the direction of Contractor or any Subcontractor or Agent For Contractor (but in all cases, excluding (i) Pre-Existing Hazardous Substances (except to the extent of Contractor’s or its Subcontractors’ or such Agent For Contractor’s noncompliance with Section 3.8.46; or (ii) Gross Negligence or Willful Misconduct of (1) Senior Supervisory Personnel or (2) comparable personnel of a Subcontractor or Agent For Contractor (limited to the extent of any recovery by Contractor from such Subcontractor or Agent For Contractor) in the handling, storage or transportation of any Pre-Existing Hazardous Substance after discovery of such Pre-Existing Hazardous Substance by Contractor or a Subcontractor or Agent For Contractor); or (iii) claims arising out of Owner’s Gross Negligence or Willful Misconduct in the handling, storage or transportation of Hazardous Substances brought to the Site by Contractor), (b) bodily injuries (including wrongful death) or property damage of Third Parties (with respect to bodily injuries, “Third Parties” shall include Owner’s employees), to the extent caused by the negligent acts or omissions of Contractor, any worker or any Subcontractor or anyone for whose acts they may be liable arising in connection with the performance of the Work, (c) fines and penalties arising out of the violation by Contractor or any Subcontractor of: (i) any Permit held in its name or (ii) any applicable Law, (d) any claims brought by Subcontractors against Owner claiming Contractor breach of contract with such Subcontractor including failure to make payments due and payable to such Subcontractor (except to the extent the same constitute Reimbursable Costs), (e) the vitiation of any Contractor provided insurance policies due to Contractor’s or any Subcontractor’s breach of any representation, declarations or conditions contained in any insurance policy, including the provision of false or misleading information, (f) Contractor or any Subcontractor terminating the employment of or removing from the Work any employee who fails to meet the requirements set forth in Section 5.1.2 following a request by Owner to have such employee removed from Work, or (g) claims by any Government Authority as a result of a failure by Contractor or any Subcontractor to pay Taxes for which it is responsible to pay or remit under this Agreement.

30.1.3 To the fullest extent permitted by Law, Contractor assumes liability for, and agrees to indemnify, protect, save and hold harmless and defend each of the Owner Indemnitees from and against any and all Losses (including any strict liability, as well as reasonable attorneys’ fees, consultant fees, experts’ fees and litigation expenses) of whatsoever kind and nature that may be imposed on, suffered or incurred by or asserted against any Owner Indemnitee to the extent arising from the negligence of Contractor or any Subcontractor or any other Person directly or indirectly employed by any of them hereunder for damage to or loss of the physical property of Owner or its Affiliates for which Owner or its Affiliate has assumed care, custody and control (excluding, for the avoidance of doubt, the Work for which Contractor has the risk of loss under Section 25.2 at the time the damage occurred); provided, however, Contractor’s and Subcontractor’s total liability hereunder for each occurrence of such damage or loss to such property is capped at [***].

 

108


 

30.1.4 Notwithstanding anything to the contrary herein, no provision, clause, covenant, or agreement contained in, or collateral to this Agreement, will be understood to require Owner or Contractor to indemnify, defend, hold harmless, or have the effect of indemnifying, defending, or holding harmless, any indemnitee from or against any liability for loss or damage to the extent resulting from the Gross Negligence or Willful Misconduct of the indemnitee, an agent or employee of the indemnitee, or a third party over which the indemnitor has no control.

 

30.2

OWNER INDEMNITY.

Subject to Contractor’s indemnity obligations under Section 30.1, to the fullest extent permitted by Law, Owner assumes liability for, and agrees to indemnify, protect, defend, save and hold each of the Contractor Indemnitees harmless from and against any and all Losses (including any strict liability, as well as reasonable attorneys’ fees, consultant fees, experts’ fees and litigation expenses) of whatsoever kind and nature that may be imposed on, suffered or incurred by or asserted against any Contractor Indemnitee: (i) arising out of or due to a claim or action made by any third party (which third party shall not include any Contractor Indemnitee) to the extent caused by or arising directly from the negligence, Gross Negligence or Willful Misconduct of Owner, its Affiliates or Owner Contractors or their officers or employees while engaged in the performance of any activities in connection with this Agreement and (ii) for any claims arising out of Pre-Existing Hazardous Substances on the Job Site (except to the extent Contractor is otherwise liable as set forth in Section 30.1.2(a)(i)).

 

30.3

ACTIONS BY EMPLOYEES.

In any and all claims against any indemnified person by any employee of Contractor or any Subcontractor or by anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, the indemnification obligation stated above shall not be limited in any way by any limitation on the amount or type of damages, compensation or benefits payable by or for Contractor or any Subcontractor under the applicable workers’ compensation benefit acts, disability statute or other employee benefit acts.

 

30.4

NOTICE AND DEFENSE.

30.4.1 Subject to the foregoing provisions of this Article 30, within fifteen (15) days of receipt by an indemnified party under this Article 30 of notice of the commencement of any action, such indemnified party will, if a claim in respect thereof is to be made against the indemnifying party under Section 30.1 or Section 30.1.4 above, provide Notice to the indemnifying party of the commencement thereof. The indemnifying party shall have no liability under this Article 30 for any claim or action for which the indemnified party has admitted any liability or which such Notice is not provided to the extent that such failure to give Notice actually and materially prejudices the indemnifying party’s ability to defend against such claim. In case any such action is brought against any indemnified party and it provides Notice to the indemnifying party of the commencement thereof, the indemnifying party shall assume on behalf of such indemnified party, and conduct with due diligence and in good faith, the defense of any such action against such person, whether or not the indemnifying party is joined therein; provided, however, that, without relieving the indemnifying party of its obligations hereunder, the indemnified party may elect to participate, at its expense, in the defense of any such suit. The indemnifying party shall have the

 

109


 

right to assume the defense of any such claim or action with counsel designated by the indemnifying party and reasonably satisfactory to the indemnified party, provided, however, that if the defendants in any such action include both indemnifying party and the indemnified party, and the indemnified party shall have reasonably concluded that there may be legal defenses available to it which are different from or additional to those available to the indemnifying party, the indemnified party shall have the right to select separate counsel to assert such legal defenses and to otherwise participate in the defense of such action on behalf of such indemnified party, the cost of which shall be subject to indemnification under this Article 30.

30.4.2 Should any indemnified party be entitled to indemnification under this Article 30 and should the indemnifying party fail to assume the defense of such claim or action, the indemnified party may, at the expense of the indemnifying party contest (or, with the prior consent of the indemnifying party, settle) such claim or action. No indemnifying party shall, without the prior written consent of the indemnified party, effect any settlement of any pending or threatened action in respect of which any indemnified party is or could have been a party and indemnity could have been sought hereunder by such indemnified party unless such settlement includes an unconditional release of such indemnified party from all liability on any claims that are the subject matter of such a pending or threatened action.

 

30.5

REMEDIES NOT EXCLUSIVE.

The rights of indemnity shall not be exclusive with respect to any other right or remedy provided for herein.

 

30.6

TAX EFFECT OF INDEMNIFICATION.

Notwithstanding anything to the contrary contained herein, any indemnity payments owed by a Party shall be reduced by any tax benefits to the indemnified Person and increased by any tax detriments to the indemnified Person resulting from such indemnity payment (including tax detriments resulting from any additional indemnity payments pursuant to the provisions of this Section 30.6), such tax benefits or detriments, if not mutually agreed by the Parties, to be determined by an independent, mutually agreed upon tax consultant.

 

31.

EVENTS OF DEFAULT; REMEDIES.

 

31.1

CONTRACTOR EVENTS OF DEFAULT.

Contractor shall be in default of its obligations under this Agreement if any of the following events arise or exist and is continuing and Contractor shall fail to remedy the same within [***] after Owner’s Notice of the occurrence of such event, or if such remedy cannot reasonably be completed in such time, Contractor shall fail promptly to commence and diligently (a) pursue remedial action within such period and (b) conclude such action as soon as practicable (and in any event within [***] after the occurrence of such event); provided, however, that (i) no such cure period shall be allowed as to Sections 31.1.1, 31.1.3, 31.1.4, 31.1.7, 31.1.8, and 31.1.16 and (ii) with respect to Sections 31.1.2, 31.1.6 and 31.1.9 the sole cure period shall be as set forth therein:

 

110


 

31.1.1 Contractor or any JV Member or Contractor Guarantor commences any case, proceeding or other action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of itself or its debts or assets, or adopts an arrangement with or makes an assignment for the benefit of creditors, under any bankruptcy, moratorium, rearrangement, insolvency, reorganization or similar law for the relief of creditors or affecting the rights or remedies of creditors in general or is declared insolvent or Contractor or any JV Member or Contractor Guarantor conceals or removes any part of its property with the intent to hinder, delay or defraud its creditors, or makes or suffers any transfer of its property which may be fraudulent under applicable Law, or admits in writing its inability to pay its debts; provided, however, any of the foregoing events affecting only a JV Member shall not be a Contractor event of default if and for so long as (i) Contractor is continuing to perform all of its obligations under this Agreement and (ii) the Contractor Guarantees remain in full force and effect and are unimpaired;

31.1.2 there shall be instituted against Contractor or any JV Member or Contractor Guarantor any case, proceeding or action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of Contractor or any JV Member or Contractor Guarantor or its debts or assets, which shall not have been terminated, stayed or dismissed within [***] after commencement, or a trustee, receiver, custodian or other like official is appointed for or to take possession of all or any part of the property or assets of Contractor or any JV Member or Contractor Guarantor, or Contractor or any JV Member or Contractor Guarantor generally does not pay its debts as they become due; provided, however, any of the foregoing events affecting only a JV Member shall not be a Contractor event of default if and for so long as (i) Contractor is continuing to perform all of its obligations under this Agreement and (ii) the Contractor Guarantees remain in full force and effect and are unimpaired;

31.1.3 Contractor assigns or transfers this Agreement or any of its rights or interests herein, except as expressly permitted hereunder, or a Contractor Guarantor assigns or transfers the Contractor Guarantee to which it is a party;

31.1.4 Contractor disregards or fails to comply with any Laws, Permit, Applicable Codes and Standards or any instruction regarding Contractor’s performance of the Work given by Owner’s Representative in writing in accordance with this Agreement;

31.1.5 any representation or warranty made by Contractor herein was materially inaccurate or misleading when made;

31.1.6 any Performance Security is not delivered to Owner within [***] of when due in accordance with this Agreement, or if delivered to Owner, expires or is terminated or repudiated, and is not replaced by Contractor as required in accordance with the express terms of this Agreement;

31.1.7 an Abandonment of the Project occurs;

31.1.8 Contractor, after a delay in or suspension of the Work permitted by this Agreement, fails or refuses to commence performance of the Work after the cessation of such delay or suspension as provided in Section 17.1;

 

111


 

31.1.9 Contractor fails to pay or cause to be paid any undisputed amount that is due and payable to Owner within [***] from the date such payment is due;

31.1.10 Contractor fails to maintain in full force and effect insurance policies of such types, in such amounts and with such deductibles, as are required pursuant to this Agreement;

31.1.11 Contractor fails to make prompt, undisputed payments when due to Subcontractors for labor, materials or equipment;

31.1.12 Contractor suspends performance of a material portion of the Work (other than as provided in Section 17.1.1, Section 17.1.3, Article 33 or pursuant to a Change Order);

31.1.13 Contractor defaults in its observance or performance of any of the terms, conditions and/or restrictions of Article 40;

31.1.14 Contractor fails to make good any Defects, Deficiencies or damage as described in Section 20.5;

31.1.15 Contractor fails to discharge or bond liens filed as required under this Agreement;

31.1.16 Contractor becomes legally domiciled in the State of Louisiana;

31.1.17 Contractor’s liability for any of LPS1 Schedule Delay Liquidated Damages, LPS2 Schedule Delay Liquidated Damages, LPS3 Schedule Delay Liquidated Damages, LPS4 Schedule Delay Liquidated Damages or Facility Substantial Completion Schedule Delay Liquidated Damages exceeds the LPS1 Schedule Delay Liquidated Damages Cap, LPS2 Schedule Delay Liquidated Damages Cap, LPS3 Schedule Delay Liquidated Damages Cap, LPS4 Schedule Delay Liquidated Damages Cap or Facility Substantial Completion Schedule Delay Liquidated Damages Cap, respectively;

31.1.18 Contractor ceases to be wholly-owned by the JV Members, collectively, for any reason, other than as the result of one JV Member having defaulted under the terms of the JV Agreement so long as at all times following such cessation due to such default: (a) Contractor continues to perform all of its obligations under this Agreement, and (b) the Contractor Guarantees remain in full force and effect and are unimpaired;

31.1.19 the JV Agreement is terminated as a result of the default of only one of the JV Members at any time prior to the end of the Warranty Period; provided that it shall not be a Contractor event of default if at all times following such termination: (a) Contractor continues in existence as a limited liability company under the laws of the State of Texas, (b) Contractor continues to perform all of its obligations under this Agreement and (c) the Contractor Guarantees are in full force and effect and unimpaired;

31.1.20 a Contractor Guarantor materially breaches its obligations under the Contractor Guarantee to which it is a party; and

 

112


 

31.1.21 Contractor defaults in its observance or performance of any other material provision hereunder (except defaults for which the payment of liquidated damages is the sole and exclusive remedy as provided in Article 22).

 

31.2

REMEDIES.

31.2.1 In the event that a Contractor default identified in Section 31.1 is continuing following the applicable cure periods described in Section 31.1.1, Owner shall have any or all of the following rights and remedies, and Contractor shall have the following obligations:

(a) Owner, without prejudice to any of its other rights or remedies under this Agreement, may unilaterally terminate this Agreement immediately by delivery of a Notice of termination to Contractor;

(b) If requested by Owner, Contractor shall withdraw from the Job Site, assign to Owner its rights and obligations under such Subcontracts as Owner may request, and remove such Materials, construction equipment, tools and instruments used by and any debris or waste materials generated by Contractor in the performance of the Work, and Owner, at its sole option, may enter onto the Job Site and take possession of all equipment, tools, supplies, scaffolding and machinery rented by Contractor, any and all designs, remaining Materials (and special tools comprising Materials), Subcontracts, correspondence, schedules, Deliverables and facilities of Contractor that Owner deems necessary to complete of the Work;

(c) Owner, without incurring any liability to Contractor, shall have the right (either with or without the use of the Materials, tools and instruments) to have the Work finished by itself or by another contractor; and

(d) Owner may recover amounts owing to it (as calculated in accordance with Section 31.3 below) by Contractor by enforcing its rights in respect of the Performance Security.

31.2.2 Owner may, without prejudice to any of its other rights or remedies, (a) seek performance by either or both of the Contractor Guarantors or any other guarantor of Contractor’s obligations hereunder, (b) seek equitable relief to cause Contractor to take action or to refrain from taking action pursuant to this Agreement, or to make restitution of amounts improperly received under this Agreement, (c) make such payments or perform such obligations as are required to cure such Contractor default, draw on or make a claim against any Performance Security or other security provided pursuant to this Agreement and/or offset the cost of such payment or performance against payments otherwise due to Contractor under this Agreement; provided that Owner shall be under no obligation to cure any such Contractor default or (d) seek damages as provided in Section 31.3, including proceeding against any bond, letter of credit or guarantee given by or for the benefit of Contractor for its performance under this Agreement.

 

31.3

DAMAGES.

In the event of any default by Contractor under Section 31.1 and termination by Owner of this Agreement pursuant to Section 31.2.1, Contractor shall, subject to Section 21.1, be liable to Owner for the amount of any costs and expenses reasonably incurred by Owner or any Person acting on Owner’s behalf in completing the Work and other expenses and fees related thereto in

 

113


 

an attempt to achieve Final Completion by the Final Completion Deadline, or if such date has already passed, at the earliest possible date, less any amounts Owner would have been obligated to pay to Contractor as Total Costs hereunder in respect of completing such Work assuming this Agreement had not been so terminated (collectively, the “Cover Costs”), but only to the extent that (x) the aggregate sum of Cover Costs plus (i) all amounts paid or payable to Contractor under this Agreement prior to termination of this Agreement; plus (ii) amounts or costs paid or incurred by Owner prior to termination of this Agreement that have been included in the calculation of Total Costs pursuant to this Agreement, exceeds (y) the Target Price. See Exhibit B-3 for example calculations of Cover Costs. Owner shall be entitled to withhold further payments to Contractor until Owner determines or it is determined pursuant to the dispute resolution provisions set forth in Article 36 that Contractor is entitled to further payments. Promptly following Final Completion, the calculation of Cover Costs shall be determined by Owner, and Owner shall notify Contractor in writing of the amount, if any, that Contractor shall pay to Owner or Owner shall pay to Contractor, which amount shall be paid within thirty (30) Days of Notice from Owner.

 

31.4

OWNER REMEDIES.

Unless stated otherwise herein, the remedies of Owner set forth herein in respect of Contractor’s obligations and liabilities are in addition to any other remedies that might otherwise be available to Owner at law or in equity.

 

31.5

OWNER DEFAULT.

31.5.1 The following shall constitute a default by Owner:

(a) Subject to the provisions of this Agreement excusing such action, Owner shall fail to pay when due any undisputed amount under this Agreement and such failure shall continue uncorrected for a period for [***] Days after Notice thereof from Contractor;

(b) Owner commences any case, proceeding or other action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of itself or its debts or assets, or adopts an arrangement with or makes an assignment for the benefit of creditors, under any bankruptcy, moratorium, rearrangement, insolvency, reorganization or similar law for the relief of creditors or affecting the rights or remedies of creditors in general or is declared insolvent or Owner conceals or removes any part of its property with the intent to hinder, delay or defraud its creditors, or makes or suffers any transfer of its property which may be fraudulent under applicable Law, or admits in writing its inability to pay its debts; and

(c) There has been instituted against Owner any case, proceeding or action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of Owner or its debts or assets, which shall not have been terminated, stayed or dismissed within [***] Days after commencement, or a trustee, receiver, custodian or other like official is appointed for or to

take possession of all or any part of the property or assets of Owner, or Owner generally does not pay its debts as they become due; provided, however, that Owner shall have [***] Days to cure this default following Notice thereof from Contractor.

31.5.2 Contractor shall have the right to terminate this Agreement upon the occurrence of a default by Owner by delivery of a Notice of termination to Owner. Upon such termination,

 

114


 

Contractor will be compensated (i) the Reimbursable Costs, Contractor’s G&A and Contractor’s Margin for all Work performed through the date of termination, and (ii) the reasonable costs to demobilize and any unavoidable cancellation charges from Subcontractors. Any such termination shall not relieve Contractor of its obligations to perform Corrective Work during any applicable Warranty Period.

 

31.6

OBLIGATIONS UPON TERMINATION.

31.6.1 Any termination of this Agreement (whether by Owner or Contractor) shall not relieve (a) Contractor and Owner of each of its obligations with respect to confidentiality as set forth herein, (b) any Party of any obligation hereunder which expressly or by implication survives termination hereof, (c) Owner of its obligation to pay amounts owing to Contractor pursuant to Section 31.5.2 and (d) any Party of its indemnity obligations or liabilities for loss or damage to another Party in accordance with this Agreement, and shall not relieve Contractor of its obligations and liabilities for the portions of the Work already completed prior to the date of termination.

31.6.2 Upon a termination of this Agreement pursuant to this Article 31 or Article 32: (a) Contractor shall leave the Job Site and remove from the Job Site all Contractor equipment, waste, rubbish and Hazardous Substances as Owner may request; (b) Owner shall take possession of the Job Site and of the Materials (whether at the Job Site, in transit or otherwise); (c) except as otherwise directed by Owner, Contractor shall promptly assign to Owner or its designee any contract rights (including warranties, licenses, patents and copyrights) that it, or any of its Subcontractors, has to any and all Materials, Deliverables and the Work, including contracts with Subcontractors and Contractor shall execute such documents as may be reasonably requested by Owner to evidence such assignment, subject to Owner’s assumption of same and, if required, Owner’s adequate assurance to such Subcontractors regarding Owner’s ability to pay; (d) to the extent so directed by the Owner, Contractor shall cancel as quickly as possible and upon terms satisfactory to Owner all orders placed by it with Subcontractors and shall use all reasonable efforts to minimize cancellation charges and other costs and expenses associated with the termination of this Agreement unless Owner elects to take assignment of any such Subcontracts; (e) Contractor shall cooperate with Owner for the efficient transition of the Work and thereafter shall use commercially reasonable efforts to execute that portion of the Work as may be necessary to preserve and protect Work already in progress and to protect Materials at the Job Site or in transit thereto, and to comply with any applicable Law, Permits and any Applicable Codes and Standards; (f) Contractor shall promptly furnish Owner with copies of all Deliverables, Auto CAD compatible electronic files, Drawings and Specifications and, to the extent available, final “as-built” drawings, in compliance with Exhibit J; (g) Contractor shall provide Owner and its designee with the right to use, free of charge, all other patented, copyrighted and other proprietary information or Intellectual Property relating to the Work that Owner deems necessary to complete the Work, and Contractor shall execute such documents as may be reasonably requested by Owner to evidence such right; (h) Contractor shall assist Owner in preparing an inventory of all Materials in use or in storage at the Job Site; and (i) Contractor shall take such other action as required hereunder upon termination of this Agreement. In the event that Contractor terminates this Agreement pursuant to and in accordance with Section 31.5.2, Contractor shall not be obligated to comply with paragraphs (c) through (h) (inclusive) of this Section 31.6.2(b) unless and until a Lender or another Person on behalf of Owner has cured, or has agreed in writing to cure, Owner’s default.

 

115


 

32.

TERMINATION FOR CONVENIENCE.

 

32.1

GENERAL.

32.1.1 Owner may in its sole discretion terminate the Work without cause at any time by giving Notice of termination to Contractor and such termination shall be effective upon the giving of such notice by Owner. If the Work is terminated by Owner without cause, Owner and Contractor shall have the following rights, obligations and duties:

(a) upon receiving any Notice of termination, Contractor shall stop performing the Work and, except for Subcontracts that Owner elects to take assignment of or as otherwise directed by Owner, shall cancel as quickly as possible all orders placed by it with Subcontractors and shall use all reasonable efforts to minimize cancellation charges and other costs and expenses associated with the termination of this Agreement;

(b) if Owner terminates the Work pursuant to this Section 32.1 after the issuance of a Limited Notice to Proceed, Contractor will be compensated for the Work performed under such Limited Notice to Proceed through the date of termination, plus reasonable costs to demobilize and any unavoidable and reasonable cancellation charges from Subcontractors under Subcontracts not assumed pursuant to Section 32.1.1(c); provided, however, that the amount payable for the Work actually completed by Contractor shall be subject to adjustment to the extent the Work requires Corrective Work;

(c) following a termination by Owner pursuant to this Section 32.1, Owner shall have the right, at its option, to assume and become liable for any reasonable written obligations and commitments that Contractor may have in good faith undertaken with third parties in connection with the Work, which obligations and commitments are not covered by the payments made to Contractor under Section 32.1.1(b). If Owner elects to assume any obligation of Contractor as described in this Section 32.1.1(c), then, as a condition precedent to Owner’s compliance with any section of this Article 32, Contractor shall execute all papers and take all other reasonable steps requested by Owner which may be required to vest in Owner all rights, set-offs, benefits and titles necessary to such assumption by Owner of such obligations described in this Article 32; and

32.1.2 Notwithstanding anything to the contrary contained herein, in the event Owner terminates this Agreement pursuant to this Article 32 for any reason prior to the issuance of a Limited Notice to Proceed or, if no Limited Notice to Proceed is issued, prior to the issuance of the Notice to Proceed, Contractor shall not be entitled to any remuneration from Owner.

 

32.2

CLAIMS FOR PAYMENT FOLLOWING TERMINATION FOR CONVENIENCE.

Any claim for payment by Contractor under this Article 32 must be made within sixty (60) Days after the effective date of a termination hereunder, and Owner’s payment thereof shall be made pursuant to the payment protocol set forth in Article 6.

 

116


 

33.

FORCE MAJEURE.

 

33.1

EXTENSION OF TIME FOR FORCE MAJEURE EVENT.

An equitable adjustment of the Target Price or any component thereof and of scheduled and guaranteed dates shall be granted to Contractor pursuant to a Change Order for a Force Majeure Event. The Parties acknowledge that this Agreement does not reflect the impact of the COVID-19 epidemic as of the Effective Date, if any. To the extent adverse impacts pertaining to the COVID-19 epidemic (such as those adversely affecting productivity) arise after the Notice to Proceed Date, each Party shall continue to work in good faith to mitigate any resulting impact, and shall be entitled, if and to the extent applicable, to relief pursuant to and in accordance with this Article 33.

 

33.2

CONTRACTOR’S RESPONSIBILITY.

33.2.1 Contractor shall work diligently to cure, remove, otherwise correct, minimize and contain all costs and expenses attendant on or arising from each Force Majeure Event including expenditures for avoidance or reduction of the effect of a Force Majeure Event. The failure of Contractor to perform such Work shall be reason for denial of the full extension of time, which would otherwise be justified. The extension of time for a Force Majeure Event shall be that duration of time jointly and reasonably determined by Owner, the Independent Engineer and Contractor to be reasonably necessary to make up the aggregate amount of time actually lost across all affected activities, all pursuant to the Change Order provisions of Article 12.

33.2.2 Contractor shall provide Notice of any Force Majeure Event to Owner and the Independent Engineer upon obtaining actual knowledge of the occurrence of such Force Majeure Event pursuant to and in accordance with Section 12.2.1.

 

33.3

CONTINUING RESPONSIBILITY OF CONTRACTOR.

If a Force Majeure Event occurs, Contractor shall remain responsible for completing the Work in accordance with the Project Schedule as adjusted pursuant to a Change Order.

 

33.4

PERFORMANCE NOT EXCUSED.

The payment of money owed shall not be excused because of a Force Majeure Event or Owner Caused Delay. In addition, neither Owner nor Contractor shall be excused under this Article 33 from timely performance of their obligations hereunder to the extent that a claimed Force Majeure Event was caused by any negligent or intentional acts, errors or omissions Willful Misconduct or for any breach or default of this Agreement by such Party. Furthermore, no suspension of performance or extension of time shall relieve the Party benefiting therefrom from any liability for any breach of the obligations that were suspended or failure to comply with the time period that was extended to the extent such breach or failure occurred prior to the occurrence of the applicable Force Majeure Event or Owner Caused Delay. Notwithstanding anything to the contrary contained herein, Contractor shall not be entitled to any adjustment to the Target Price in respect of demobilization and/or remobilization required as a result of any Force Majeure Event.

 

117


 

34.

DUTIES AND TAXES.

 

34.1

ALLOCATION OF RESPONSIBILITIES.

Contractor shall pay and administer, as Direct Costs, any and all Taxes payable in connection with the Work including, but not limited to Taxes imposed on services and Contractor’s purchase or rental of equipment, tools, and supplies used by Contractor in the performance of the Work, or the Materials incorporated into, installed in, or affixed or attached to the Facility; provided, however that any Taxes based on or related to the net income, capital or net worth of Contractor or any Subcontractor or Agent For Contractor shall be Non-Reimbursable Costs. Notwithstanding anything in the Agreement to the contrary, Owner shall be solely responsible for and shall, as required by applicable Law, pay the appropriate Government Authority all property taxes and other Taxes directly associated with: (i) its ownership and operation and maintenance of the Job Site, the Facility, and any Materials to be installed in, incorporated into, or affixed or attached to the Facility, and (ii) the supply of the Owner Furnished Equipment and Materials and performance of the Owner Scope of Work. Contractor shall reasonably cooperate with Owner to minimize any Taxes payable by Owner hereunder. If applicable, Owner shall timely provide Contractor: (i) a schedule identifying any portion of the Work eligible for exemption from Taxes; and (ii) a valid exemption certificate or any other documentation required by applicable Laws, demonstrating Owner’s eligibility for such exemption. Owner shall indemnify, defend, and hold Contractor harmless from and against all Taxes: (i) arising from disallowance of any exemption asserted by Owner under the Agreement; or (ii) Owner’s failure to comply with its Tax obligations under the Agreement.

 

34.2

LOUISIANA TAX AND INCENTIVES PROVISIONS.

Pursuant to state Law, certain tax and incentive programs are available to qualifying manufacturers in certain circumstances, including the Louisiana Quality Jobs Program, Enterprise Zone Program, and the Manufacturing Machinery and Equipment sales tax exclusion. Owner has not determined which, if any, of these programs it will pursue. Contractor shall reasonably cooperate with and assist Owner and any designated tax and incentive consultant, and shall require Subcontractors and Agent For Contractors to reasonably cooperate with and assist Owner and any designated tax and incentive consultant, in obtaining tax and incentive benefits under these and any other available programs. Such assistance may include, but is not limited to, documenting purchase transactions, providing reports and supporting documents required to be submitted to obtain the tax and incentive benefits, and acting as agent for Owner in connection with the purchase of manufacturing machinery and equipment.

 

35.

BINDING AGREEMENT; ASSIGNMENT.

 

35.1

BY OWNER.

The terms of this Agreement shall be binding upon Owner and its successors and assigns. Without the prior consent of Contractor, Owner may, upon prior written Notice to Contractor, assign all or part of Owner’s right, title and interest herein to any Lenders, any Affiliate of Owner, any successor to Owner’s business (whether by merger, acquisition or otherwise) or to any financially responsible assignee that agrees to be bound by the terms hereof. In addition, Owner

 

118


 

may assign all or part of its right, title and interest herein to any other Person with the prior written approval of Contractor, which approval shall not be withheld unreasonably. Contractor acknowledges that the Lenders may under certain circumstances foreclose upon and sell, or cause Owner to sell or lease the Facility and cause any new lessee or purchaser of the Facility to assume all of the interests, rights and obligations of Owner arising under this Agreement. In such event, Contractor agrees to the assignment by Owner and the Lenders of this Agreement and its rights herein to such purchaser or lessee and shall release Owner and the Lenders from all obligations hereunder upon any such assignment, provided that such new lessee or purchaser assumes Owner’s obligations under this Agreement.

 

35.2

BY CONTRACTOR.

The terms of this Agreement shall be binding upon Contractor and its successors and permitted assigns, provided that assignment by Contractor of this Agreement or any partial or total interest therein without Owner’s and the Lenders’ prior written consent (at their sole and unfettered discretion) shall be null and void.

 

36.

DISPUTES.

 

36.1

DISPUTE RESOLUTION.

36.1.1 Any dispute, controversy or claim between the Owner and Contractor that arises out of, under or in connection with this Agreement, including its interpretation, performance, enforcement, termination, validity or breach (each a “ Dispute”) shall be subject to resolution under this Article 36, which shall be the exclusive dispute resolution method for any such Dispute. If Owner or Contractor wish to declare a Dispute they shall deliver to the other Party a written notice identifying the disputed issue (a “Notice of Dispute”).

36.1.2 Following the delivery of a Notice of Dispute, the Parties will attempt in good faith to resolve such Dispute promptly through negotiation. If the Dispute has not been resolved within thirty (30) days after the date on which the Notice of Dispute was delivered, then any Party shall be permitted to submit such Dispute to binding arbitration in accordance with Section 36.1.3.

36.1.3 Any Dispute that is not resolved pursuant to Section 36.1.2 shall be exclusively and definitively resolved through final and binding arbitration conducted in accordance with the Rules of Arbitration of the ICC, which (save as modified by this Section 36.1.3) are deemed to be incorporated by reference into this Section 36.1.3.

(a) The arbitration tribunal shall consist of three (3) arbitrators. One (1) arbitrator shall be appointed by Owner, one (1) arbitrator shall be appointed by Contractor, and the third arbitrator shall be selected by agreement of the first two (2) arbitrators. If either of the first two (2) appointments is not made within thirty (30) Days after the request for arbitration, or if the first two (2) arbitrators fail to agree on a third arbitrator within thirty (30) Days after the later of them has been appointed, the unfilled appointment will be made, at the request of either Owner or Contractor, by the ICC. No arbitrator appointed pursuant to this Section 36.1.3(a) shall be an employee, agent, competitor or former employee, agent or contractor of, or have or have had any material interest (directly or indirectly) in the business of or in any Party or any of its Affiliates.

 

119


 

Each arbitrator shall be knowledgeable with respect to engineering, procurement and construction contracts and shall be fluent in the English language.

(b) Unless the Parties agree in writing otherwise:

(i) the seat of arbitration shall be New York, New York, and the language to be used in the proceedings shall be English;

(ii) the arbitrators shall, by majority vote, render a written award stating the reasons for their award within three (3) months after any hearing conducted has been concluded. The arbitral award may contain such orders (including orders for specific performance, setoff, other equitable relief or monetary damages) in respect of or affecting any of the Parties (and/or any Loss suffered by any of them), as such arbitral tribunal determines to be appropriate in the circumstances; provided that the arbitral tribunal shall not have the authority to award any indirect, consequential or punitive damages unless, but only to the extent, such damages are expressly permitted hereunder;

(iii) the Parties and the arbitral tribunal will ensure that the arbitration proceedings and any documents disclosed in such proceedings are kept strictly confidential;

(iv) the Parties may make an application to any court of competent jurisdiction for the obtaining of any evidence from third parties that the arbitrators direct may be relevant to the arbitral proceedings; and

(v) the responsibility for the costs of the arbitration will be determined by the arbitral tribunal.

(c) An arbitral award rendered in accordance with this Section 36.1.3 shall be final and binding on the Parties. The Parties agree that any arbitral award made pursuant to this Section 36.1.3 may be enforced against the Parties or their assets wherever they may be found and that a judgment upon the arbitral award may be entered (and any other applicable relief, including interlocutory relief, may be granted) in any court having jurisdiction on such matters, and subject to their respective obligations contained elsewhere herein, shall take all such actions as are necessary to give full and complete effect to the award which, in accordance with its terms, shall be binding upon and enforceable against them.

(d) No Party shall be entitled to suspend its performance under this Agreement during the pendency of any Dispute subject to this Section 36.1.3 or during the period during which any defaulting Party is attempting to remedy its non-performance of this Agreement within the periods prescribed therefor in Article 31.

(e) Nothing contained in this Article 36 shall be construed to prohibit any Party from making an application to any court of competent jurisdiction for an order of specific performance or for other injunctive or equitable relief as long as the arbitral tribunal contemplated in this Section 36.1.3 has not yet been formed.

 

120


 

36.1.4 Unless the Parties otherwise agree, no dispute, controversy or claim hereunder shall be consolidated with any other arbitration proceeding involving any third party.

 

36.2

CONTINUATION OF WORK DURING DISPUTE.

Notwithstanding any Dispute, it shall be the responsibility of Contractor to continue to prosecute all of the Work diligently and in a good and workmanlike manner in conformity with this Agreement. Except to the extent provided in Section 31.5.2, Contractor shall have no right to cease performance hereunder or to permit the prosecution of the Work to be delayed. Owner shall, subject to its right to withhold or offset amounts pursuant to this Agreement, continue to pay Contractor undisputed amounts in accordance with this Agreement; provided, however, in no event shall the occurrence of any negotiation or arbitration prevent or affect Owner from exercising its rights under this Agreement, including Owner’s right to terminate pursuant to Sections 31.2 and 32.1.1.

 

36.3

EXPERT DETERMINATION.

In the event of any disagreement between the Parties regarding the adjustment to the Cost Overrun and Cost Saving values pursuant to Exhibit X, the Parties agree in writing to submit such disagreement (an “Adjustment Dispute”) to an expert (the “Expert”) as provided in this Section 36.3. The Expert is not an arbitrator of the Adjustment Dispute and shall not be deemed to be acting in an arbitral capacity. The Party desiring an expert determination shall give the other Party to the Adjustment Dispute notice of the request for such determination. If the Parties to the Adjustment Dispute do not agree in writing upon an Expert within ten (10) days after receipt of the notice of request for an expert determination, then, upon the request of any of the Parties to the Adjustment Dispute, the International Centre for Expertise of the ICC shall appoint such Expert and shall administer such expert determination through the ICC’s Expert Rules. The Expert shall be and remain at all times wholly impartial, and, once appointed, the Expert shall have no ex parte communications with any of the Parties to the Adjustment Dispute concerning the expert determination or the underlying Adjustment Dispute. The Parties to the Adjustment Dispute shall cooperate fully in the expeditious conduct of such expert determination and provide the Expert with access to all facilities, books, records, documents, information and personnel necessary to make a fully informed decision in an expeditious manner. Before issuing a final decision, the Expert shall issue a draft report and allow the Parties to the Adjustment Dispute to comment on it. The Expert will ensure that the expert determination and any documents disclosed in such proceedings are kept strictly confidential. The Expert shall endeavor to resolve the Adjustment Dispute within thirty (30) Days (but no later than sixty (60) Days) after his appointment, taking into account the circumstances requiring an expeditious resolution of the matter in dispute. The Expert’s decision shall be final and binding on the Parties to the Adjustment Dispute unless challenged in an arbitration pursuant to Section 36.1 within thirty (30) Days of the date the Expert’s decision. If challenged: (a) the decision shall remain binding and be implemented unless and until finally replaced by an award of the arbitrators; (b) the decision shall be entitled to a rebuttable presumption of correctness; and (c) the Expert shall not be appointed in the arbitration as an arbitrator or as advisor to either Party without the written consent of both Parties.

 

121


 

37.

INDEPENDENT CONTRACTOR.

 

37.1

GENERAL.

Contractor is an independent contractor and nothing contained herein (including Section 24.5) shall be construed as constituting any relationship with Owner other than that of owner and independent Contractor, nor shall it be construed as creating any relationship whatsoever between Owner and the Contractor’s employees. Neither Contractor nor any of its employees is or shall be deemed to be employees of Owner. Contractor shall not have the authority to act on behalf of Owner or to bind Owner in any manner, except as expressly set forth herein.

 

37.2

EMPLOYEES.

Subject to Section 5.2 and Article 24 hereof, Contractor has sole authority and responsibility to employ, discharge and otherwise control its employees.

 

37.3

RESPONSIBILITY FOR SUBCONTRACTORS, ETC.

Contractor accepts complete responsibility for the acts of its agents, employees, Agent For Contractors, Subcontractors and all others it hires to perform or assist in the performance of the Work.

 

38.

NOTICES AND COMMUNICATIONS.

 

38.1

REQUIREMENTS.

38.1.1 Any Notice, request, proposal for changes, Change Order, and correspondence (including drawings, lists, schedules, instruction books, or statements) required or permitted under the terms and conditions of this Agreement shall be in writing and (a) delivered personally, (b) sent by e-mail with the receiving Party retaining a confirmation receipt (and confirming receipt thereof to sender with respect to non-routine materials), (c) sent by a recognized overnight mail or courier service, with delivery receipt requested (with respect to non-routine materials) or (d) sent by mail (return receipt requested with respect to non-routine materials), to the following addresses (or to such other address that the receiving Party may designate from time to time in accordance with this Article 38); provided, however, Requests for Payment (excluding lien waivers) need only be sent as PDF documents by e-mail in the manner described in sub-section (b):

 

122


 

If to Contractor:

If to Owner:

38.1.2 Promptly after the occurrence of the Financial Closing Date, Owner shall provide to Contractor the details for the delivery of Notices under this Agreement to the Independent Engineer and the representative(s) for the Lenders.

 

38.2

EFFECTIVE TIME.

A Notice delivered in accordance with Section 38.1 shall be deemed to have been delivered upon the receipt thereof.

 

38.3

TECHNICAL COMMUNICATIONS.

Any technical or other communications pertaining to the Work shall be between the Contractor’s Representative and Owner’s Representative or other representatives appointed by the Parties. Each Party shall give Notice to the other of the name of such representative or representatives. The Contractor’s Representative shall be satisfactory to Owner, have knowledge of the Work and be available at all reasonable times for consultation.

 

123


 

39.

FINANCING MATTERS.

Owner contemplates obtaining financing (including any refinancing thereof) for the Facility consisting of one or more construction or permanent loans to be secured by all or a portion of the Facility and its rights under this Agreement and certain equity contributions (the “Financing”). In the event Owner applies for or obtains any Financing, Contractor shall, notwithstanding the existence of any Dispute between the Owner and Contractor, promptly execute or consent to a Consent and Agreement in the form attached hereto as Exhibit F-5 (the “Consent and Agreement”), including any additional terms or provisions reasonably requested by any of the Lenders, an Indemnity Undertaking in favor of the title insurance providers in the form attached hereto as Exhibit F-14 from each of Contractor and each Contractor Guarantor, and such other documents, which are reasonably required by the Lenders in connection with such Financing and which are in form and substance reasonably acceptable to the Parties (collectively, the “Financing Deliverables”); provided, however, that Contractor shall have a reasonable period of time prior to the execution of each Financing Deliverable within which to review any such documents. So long as the Lenders’ requested terms or provisions do not materially change or impact the terms of this Agreement, they shall be deemed reasonable. Contractor shall respond to reasonable requests by the Lenders for certificates and legal opinions as well as information regarding the qualifications, experience, past performance and financial condition of Contractor and other matters pertaining to Contractor’s participation hereunder and in the Facility. Contractor’s obligations under this Article 39 shall extend until at least the end of the Warranty Period.

 

40.

COMPLIANCE WITH LAWS.

 

40.1

ANTI-CORRUPTION.

40.1.1 Contractor represents, warrants and covenants that neither it, nor any of its Affiliates (or any of their respective principals, partners or funding sources), is currently (a) a Person designated by the U.S. Department of Treasury’s Office of Foreign Assets Control as a “specially designated national or blocked person” (“SDN”) or similar status, (b) a person otherwise identified by a government or legal authority as a person with whom Owner is prohibited from transacting business, (c) directly or indirectly owned or controlled by an SDN or the government of any country that is subject to an embargo by the government of the United States of America or (d) a Person acting on behalf of an SDN or a government of any country that is subject to an embargo by the government of the United States of America. Contractor agrees that it will notify Owner in writing immediately upon the occurrence of any event that subsequently results in any of the designations set forth in this Section 40.1.1.

40.1.2 Each Party shall, in the performance of this Agreement, comply with all laws, orders, directives, and regulations in effect on the Effective Date and as they may be amended from time to time that are applicable to the Party. Notwithstanding anything to the contrary contained herein, this Agreement shall not be interpreted or applied so as to require a Party to do, or to refrain from doing, anything that would constitute a violation of federal or state laws and regulations applicable to it, including the Foreign Corrupt Practices Act of 1977, 15 U.S.C. § 78dd-2, the OECD Anti-Bribery Convention, the U.K. Bribery Act of 2010, E.U. and E.U. member country anti-bribery and corruption laws, laws or regulations restricting participation in or compliance with certain foreign boycotts, directly or indirectly, as contained in the U.S. Export

 

124


 

Administration Act of 1979, the U.S. Internal Revenue Code or any similar statute, regulation, order or convention binding on the Party, as each may be amended from time to time, and including implementing regulations promulgated pursuant thereto (collectively, the “Anti-Corruption Laws”). Without limiting the foregoing, each Party agrees on behalf of itself, its Affiliates and their respective directors, officers, employees, agents and contractors, not to pay any fees, commissions or rebates to any employee, officer or agent of the other Party or its Affiliates or their respective shareholders, or provide or cause to be provided to any of them any gifts or entertainment of significant cost or value in connection with this Agreement or in order to influence or induce any actions or inactions in connection with the commercial activities of the Parties in connection with this Agreement. Each Party further agrees to cooperate and conduct its business and activities pursuant to this Agreement in such a manner to ensure that no Party or any of their respective Affiliates is placed in a position of non-compliance with federal and state laws and regulations applicable to it, including any reporting requirements.

40.1.3 Contractor represents, warrants and covenants with respect to itself and its Affiliates that, except as disclosed by a Contractor Guarantor in public filings with the U.S. Securities and Exchange Commission (a) it and its Affiliates are being and have been operated in compliance in all material respects with the Anti-Corruption Laws, (b) neither it nor any of its Affiliates has received any written notice or claim alleging any material violation under any of the Anti-Corruption Laws, and (c) neither it nor any of its Affiliates, nor any of their respective directors, officers, or employees (or, to the best of Contractor’s knowledge and belief, any partner, intermediary or other Person acting or purporting to act on behalf of such party or any of its Affiliates) has knowingly directly or indirectly paid, offered, given, promised to pay or authorized the payment of any money or anything of value to (i) any candidate for public office, any past or present employee, director, officer, official, representative or agent of any government, government or legal authority, instrumentality, or any public international organization (“Government Official”), (ii) any Person acting for or on behalf of any Government Official, or (iii) any other Person at the suggestion, request, direction or for the benefit of any of the above-described Persons to obtain, retain or direct business or to obtain special concessions or pay for favorable treatment for business secured or for special concessions already obtained.

40.1.4 Neither Contractor nor any of its Affiliates, directors, officers, employees or agents, shall use its relationship with Owner to attempt to disguise the sources of illegally-obtained funds. Contractor further represents and warrants that no such attempt of the sort described in this Section 40.1.4 has been made prior to the Second Restatement Date.

 

40.2

RECORDS.

Contractor shall keep all records necessary to confirm compliance with Sections 40.1.1 through 40.1.4 for a period of five (5) years following the year for which such records apply. If Owner asserts that Contractor is not in compliance with Section 40.1.1, Section 40.1.2, Section 40.1.3 or Section 40.1.4, Owner shall send Notice to Contractor indicating the type of non-compliance asserted. After giving such Notice, Owner may cause an independent auditor to audit the records of Contractor in respect of the asserted non-compliance. The costs of any independent auditor under this Section 40.2 shall be paid (a) by Contractor, if Contractor is determined not to be in compliance with Section 40.1.1, Section 40.1.2, Section 40.1.3 or Section 40.1.4 or (b) by Owner, if Contractor is determined to be in compliance with Section 40.1.1, Section 40.1.2, Section 40.1.3 and Section 40.1.4.

 

125


 

40.3

EXPORT CONTROLS.

40.3.1 The Parties agree to comply with all applicable United States (“U.S.) and non-U.S. export control and economic sanctions laws in the performance of this Agreement, including any restrictions or conditions regarding the export, re-export, or other transfer of the Deliverables that are in effect now or are hereafter imposed by the U.S. or other Government Authority. Each Party shall be responsible for its own compliance with applicable export control and economic sanctions laws with regards to their Affiliates, employees, facilities and activities. These restrictions and conditions include (a) restrictions and export licensing requirements governing the export, re-export, or other transfer to other persons, entities, or countries of the Deliverables, (b) restrictions and export licensing requirements governing the export or other transfer of foreign-developed information that incorporates the Deliverables, (c) any applicable U.S. and other restrictions on the export, re-export, or other transfer of the Deliverables to countries, entities and persons that are subject to U.S. or other applicable sanctions, embargoes, or other prohibitions and (d) any applicable U.S. or other restrictions on the export or other transfer of the direct product of U.S. or other origin technical data (collectively, the “Export Controls”). Contractor shall provide Owner written Notice prior to transferring any Deliverable, commodity, software or technology that is: (i) controlled at a level greater than EAR99 under the Export Administration Regulations (“EAR”); or (ii) subject to the jurisdiction of an export control regime other than the EAR.

40.3.2 Each Party acknowledges that the other Party would not have an adequate remedy at law for money damages if the covenants contained in this Section 40.3 were breached and that any such breach would cause the other Party irreparable harm. Accordingly, each Party agrees that, in the event of any breach or threatened breach of the terms of this Section 40.3 by such Party, the other Party, in addition to any other remedies that it may have, shall be entitled, individually or jointly, without the requirement of posting a bond or other security, to equitable relief, including injunctive relief and specific performance.

 

40.4

SUBCONTRACTORS; INDEMNIFICATION.

40.4.1 Contractor agrees that with regard to any activities conducted pursuant to this Agreement, it will require its Subcontractors to agree to and comply with contractual provisions substantially equivalent to those contained in this Article 40.

40.4.2 Contractor agrees to indemnify and hold Owner, the Owner’s Affiliates and their respective shareholders, directors, officers, employees, agents, consultants or representatives harmless from any claims by Government Authorities for fines and penalties arising out of Contractor’s violation of Anti-Corruption Laws or Export Controls.

 

126


 

41.

MISCELLANEOUS.

 

41.1

FURTHER ASSURANCES AND EXPENSES.

The Parties undertake to act fairly and in good faith and use their reasonable efforts in relation to the performance and implementation of this Agreement and to take such other reasonable measures as may be necessary for the realization of its purposes and objectives, including, at the request of another Party, without further consideration, promptly executing and delivering or causing to be executed and delivered to such Party such assistance, or consents or other instruments in addition to those required by this Agreement, in form and substance satisfactory to such Party, as such Party may reasonably deem necessary or desirable to implement anything contained herein. Each Party shall pay its own costs and expenses in relation to the negotiation, preparation, execution and carrying into effect of this Agreement and the JV Agreement which, in the case of Contractor, constitute Non-Reimbursable Costs hereunder.

 

41.2

RECORD RETENTION.

Contractor agrees to retain for a period of five (5) years from the date of Final Completion all records relating to its performance of the Work, and to cause all Subcontractors and Agent For Contractors engaged in connection with the Work to retain for the same period all their records relating to the Work.

 

41.3

NO WAIVER.

No waiver of any of the terms and conditions of this Agreement shall be effective unless in writing and signed by the Party against whom such waiver is sought to be enforced. Any waiver of the terms hereof shall be effective only in the specific instance and for the specific purpose given. The failure of a Party to insist, in any instance, on the performance of any of the terms and conditions hereof shall not be construed as a waiver of such Party’s right in the future to insist on such performance.

 

41.4

SEVERABILITY.

The invalidity or unenforceability, in whole or in part, of any portion or provision of this Agreement will not affect the validity or enforceability of any other portion or provision hereof. Any invalid or unenforceable portion or provision shall be deemed severed from this Agreement and the balance of this Agreement shall be construed and enforced as if this Agreement did not contain such invalid or unenforceable portion or provision; provided, however, the Parties agree to negotiate in good faith to replace the invalid or unenforceable provision with a valid and enforceable provision that will, to the extent possible, preserve the intended economic positions of the Parties.

 

41.5

BINDING ON SUCCESSORS.

This Agreement shall be binding on the Parties hereto and on their respective successors, heirs and permitted assigns.

 

127


 

41.6

GOVERNING LAW.

41.6.1 THIS AGREEMENT SHALL IN ALL RESPECTS BE GOVERNED BY, AND CONSTRUED IN ACCORDANCE WITH THE LAW OF THE STATE OF NEW YORK WITHOUT REGARD TO PRINCIPLES OF CONFLICTS OF LAWS. Each of the Parties hereby submits to the non-exclusive jurisdiction of the federal courts or state of New York courts with venue in the State of New York for the purposes of all legal proceedings arising out of or relating to this Agreement or the transactions contemplated hereby. Each of the Parties irrevocably waives, to the fullest extent permitted by applicable Law, any objection that it may now or hereafter have to the laying of the venue of any such proceeding brought in such a court and any claim that any such proceeding brought in such a court has been brought in an inconvenient forum. The Parties agree that a judgment in any suit, action or proceeding in such a court shall be conclusive and may be enforced in other jurisdictions by suit on the judgment or by any other manner provided by law, and each of the Parties waives any defense or objection they may have regarding the validity or enforceability of any such judgment; provided, however, that such judgment shall not constitute a waiver of any rights of appeal. Nothing in this Section 41.6 shall be deemed to modify the provisions of Article 36.

41.6.2 EACH OF THE PARTIES HEREBY IRREVOCABLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY AND ALL RIGHT TO TRIAL BY JURY IN ANY LEGAL PROCEEDING ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY.

 

41.7

SET-OFF.

Notwithstanding anything to the contrary contained herein, any and all amounts owing or to be paid by Owner to Contractor hereunder, shall be subject to offset and reduction in an amount equal to any amounts that may be owing at any time by Contractor to Owner hereunder. Further, for the avoidance of doubt, with respect to anything contained herein that allows Owner to offset, set-off or draw against any Performance Security any amount then owed to Contractor, Owner shall have the express right to include in the amount offset, set-off or drawn under such Performance Security all of the reasonable costs and expenses it incurs in connection with enforcing such provision (including reasonable attorneys’ and other consultants’ fees).

 

41.8

AMENDMENT.

No amendment, modification or supplement of or to this Agreement shall be binding and effective unless in writing and signed by all of the Parties.

 

41.9

HEADINGS FOR CONVENIENCE ONLY.

The headings of the various sections contained herein are not part of this Agreement and are included solely for convenience of the Parties.

 

128


 

41.10

NONDISCRIMINATION.

Contractor agrees for and on behalf of itself and the JV Members that in the performance of the Work under this Agreement, it will not knowingly violate any applicable Laws prohibiting discrimination in employment.

 

41.11

COUNTERPART EXECUTION.

This Agreement may be executed by the Parties in any number of counterparts (and by each of the Parties on separate counterparts), each of which when so executed and delivered shall be an original, but all such counterparts shall together constitute but one and the same instrument. The .pdf or electronic signatures of the Parties shall be deemed original signatures, and .pdf or electronic copies hereof shall be deemed to constitute duplicate originals.

 

41.12

THIRD-PARTY BENEFICIARIES.

Except with respect to the rights of successors and permitted assigns as provided herein, any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders) and the rights of indemnitees under Article 30, (a) nothing contained herein nor any action taken hereunder shall be construed to create any duty, liability or standard of care to any Person that is not a Party, (b) no person that is not a Party shall have any rights or interest, direct or indirect, in this Agreement or the services to be provided hereunder and (c) this Agreement is intended solely for the benefit of the Parties, and the Parties expressly disclaim any intent to create any rights in any third party as a third-party beneficiary to this Agreement or the services to be provided hereunder.

 

41.13

SURVIVAL OF OBLIGATIONS.

Notwithstanding anything to the contrary contained herein, any termination of this Agreement shall not relieve (a) any Party of its obligations with respect to confidentiality as set forth herein, (b) any Party of any obligation hereunder which expressly or by implication survives termination hereof (including the provisions of Articles 17, 21, 24, 29, 30, 36 and 41 and Section 6.4) and (c) any Party of its obligations or liabilities for loss or damage to another Party arising out of or caused by acts or omissions of such first Party prior to the effectiveness of such termination or arising out of such termination, and shall not relieve Contractor of its obligations and liabilities for the portions of the Work already performed prior to the date of termination.

 

41.14

ENTIRE AGREEMENT.

This Agreement embodies the entire agreement among the Parties relating to the specific subject matter hereof and supersedes all prior written agreements regarding the subject matter hereof, including the First Amended and Restated Agreement. The Parties shall not be bound by or liable for any documents proposed or submitted prior to the Second Restatement Date and not incorporated into (by reference or otherwise) or referred to in this Agreement, or by or for any statement, representation, promise, inducement or understanding of any kind or nature relating to the Work or any other matter covered by this Agreement which is not set forth or provided for herein. All waivers, releases, exclusions of and limitations on liability and remedies expressly stated herein shall apply to the Parties and their respective Affiliates and employees, regardless of whether arising in contract, warranty, tort (including negligence), statutory or strict liability or otherwise.

 

129


 

41.15

RELATIONSHIP.

Nothing contained herein shall be deemed to constitute, create, give effect to, constitute any commitment to, or otherwise recognize or contemplate a joint venture, partnership or formal business entity of any kind, and the rights and obligations of the Parties shall be expressly limited only to those expressly set forth herein. There shall be no other or implied obligations hereunder, including any obligation or commitment in respect of the second phase of Plaquemines LNG (excluding LPS4) having a nameplate capacity of six decimal seven (6.7) MTPA; provided that Contractor agrees that, if an engineering, procurement and construction agreement for such second phase is entered into between Contractor and Owner (whether through a separate agreement or a further amendment and restatement of this Agreement) at any time on or prior to the first anniversary of the Second Restatement Date, such agreement shall include a target price for the work described therein that is aligned with Contractor’s pricing proposal to Owner dated June 2020 attached hereto for information only as Exhibit Z.

 

41.16

LIMITED RECOURSE.

The Parties’ sole recourse for any damages or liabilities due pursuant to this Agreement shall be limited to the remedies provided under the Contractor Guarantees, the Performance Security and the assets of the other Party and, except as provided in the Contractor Guarantees, without recourse individually or collectively to the assets of the members or the Affiliates of any other Party, the Lenders or their respective directors, agents, members, shareholders, managers, employees, representatives, partners and officers.

[Signatures appear on the following page]

 

130


 

IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed by their duly authorized representatives as of the Second Restatement Date.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC
By:  

/s/ Jonathan Thayer

Name:   Jonathan Thayer
Title:   Chief Financial Officer
KZJV LLC
By:  

/s/ Mark Welch

Name:   Mark Welch
Title:   Manager
By:  

/s/ Matt Key

Name:   Matt Key
Title:   Manager

[Second A&R EPC Agreement Signature Page]


Execution Version

 

EXHIBIT A

SCOPE OF WORK; APPLICABLE CODES AND STANDARDS

[Omitted]

 

1


Execution Version

 

EXHIBIT B-1

DIRECT COSTS AND NON-REIMBURSABLE COSTS

 

1.

Direct Costs.

1.1 Direct Costs are comprised of Direct Labor Costs and Other Direct Costs.

1.1.1 “Direct Labor Costs” means the Non-Craft Direct Labor Costs and the Craft Direct Labor Costs, in each case, incurred by Contractor with respect to the performance of the Reimbursable Work, excluding in all cases any Non-Reimbursable Costs.

 

  (a)

Non-Craft Direct Labor Costs” or “Staff” as used herein means, with respect to each category of Contractor’s non-craft employees identified in Exhibit C and the Personnel Authorization Assignment Form (PAAF), (i) the actual, verifiable and documented hours worked by such Contractor non-craft employees in the performance of the Reimbursable Work multiplied by (ii) the applicable rates set forth in Exhibit C for such Contractor non-craft employees.

 

  (b)

Craft Direct Labor Costs” means, with respect to each category of Contractor’s craft employees identified in Exhibit C and the Personnel Authorization Assignment Form (PAAF), (i) the actual, verifiable and documented hours worked by such Contractor craft employees in the performance the Reimbursable Work multiplied by (ii) the applicable rates set forth in Exhibit C for such Contractor craft employees.

1.1.2 “Other Direct Costs ” means the actual, verifiable and documented expenditures, other than (i) Direct Labor Costs and (ii) Contractor’s G&A (described in Section 3 below), incurred by Contractor while performing the Reimbursable Work, excluding in all cases any Non-Reimbursable Costs. Other Direct Costs include all costs incurred in connection with the Work including, without limitation, the following items, without duplication, unless such items are expressly stated to be Non-Reimbursable Costs:

 

  (a)

Facility expenses (including all payments made by Contractor to Subcontractors in connection with the performance of the Reimbursable Work), less amounts reimbursed or credited to Contractor by Subcontractors (including back charges for Work performed by Contractor to complete Subcontractor work or remedy Subcontractor Defects and Deficiencies, liquidated damages or otherwise);

 

  (b)

the cost of all Materials, plus related transportation, temporary storage for logistics receiving, protection and preservation, services of freight forwarding agents including logistics, boxing, packing, export preparation, customs clearance and import duties required for the performance of the Reimbursable Work;

 

1


Execution Version

 

  (c)

the cost of Permits required to be obtained by Contractor in the performance of the Reimbursable Work;

 

  (d)

the costs of third party consultants, subject to Owner’s prior approval (such approval not to be unreasonably withheld), and of manufacturers’ supervisors, service and commissioning engineer / technicians and vendor service representatives required by Contractor to perform the Reimbursable Work;

 

  (e)

the cost of inspection fees or other fees paid to Government Authorities or third party inspectors, required by Government Authorities to be paid by Contractor in the performance of the Reimbursable Work;

 

  (f)

Contractor Taxes as provided for in Section 34.1 of the Agreement;

 

  (g)

Specialized computer software or licenses, subject to Owner’s prior approval;

 

  (h)

all costs incurred by Contractor for repairing or replacing Defects or Deficiencies as provided for in Section 20.1.1 of the Agreement, including Subcontractor costs to repair or replace Defects or Deficiencies (to the extent payable to Subcontractors) and the cost of the enforcement of Subcontractor warranties with respect to the Reimbursable Work;

 

  (i)

all costs incurred by Contractor for remedying physical damage to the Reimbursable Work or the property of Owner, its Affiliates, Owners Contractors, subcontractors and vendors and any and all costs to remove and reinstall the same;

 

  (j)

currency forward contracts, hedges and options entered into by Contractor with Owner’s prior approval solely with respect to the performance of the Reimbursable Work;

 

  (k)

Contractor staff and craft relocation costs (in accordance with Contractor’s relocation policy, as provided to Owner in writing and approved by Owner (such approval not to be unreasonably withheld), cost of living adjustment, uplifts, incentives, travel and subsistence expenses, per diem, safety and performance incentives, in each case, only if such costs were incurred by Contractor in connection with the performance of the Reimbursable Work;

 

  (l)

Staff travel expenses reasonably required to perform the Reimbursable Work, including temporary duty costs, audits, and meetings at the Job Site or Owner’s offices. Travel costs for international travel that is required to perform the Reimbursable Work shall be pre-authorized by Owner. Travel shall be consistent with Contractor standard procedures, Owner Standards and subject to the following requirements:

 

  (1)

travel policies approved by Owner;

 

2


Execution Version

 

  (2)

travel time shall be billed at the applicable labor billing rate set forth in Exhibit C and the Personnel Authorization Assignment Form (PAAF), unless pre-authorized in writing by Owner; and

 

  (3)

mileage for personal vehicles shall be billed per Contractor’s normal mileage reimbursement policy.

 

  (m)

All office space not located at or adjacent to the Job Site provided by Contractor to Owner or any Owner Contractor using the rates set forth in Exhibit C;

 

  (n)

Job Site infrastructure, offices, lay down areas, temporary facilities (including offices, furnishings, fixtures, utilities, sewer, firewater systems and water), lunchrooms, craft support, facilities, safety facilities, safety and QA/QC equipment and testing apparatus, security, first aid, site cleaning or clearing as required, trash disposal, sanitary facilities, janitorial services, photography, model photographs, general drawing and office supplies (including but not limited to paper, pencils, pens, file folders, printed forms, stationary, paper cutters, staplers, drawing racks and computer discs), communications, reproduction or other graphic services, copy machines (including installation and maintenance) and all other equipment, materials, and specialty items and services required to complete the Reimbursable Work;

 

  (o)

Hourly rates or unit rates, as specified in Exhibit C, incurred in connection with Reimbursable Work including module fabrication, ship offloading (of Owner Furnished Equipment and Materials and Agent-For Equipment and Materials) and barge transfer of modules to barges for transport to the Job Site. Hourly rates and unit rates shall apply equally and without adjustment to performance of all Work, regardless of (i) large or small quantities, (ii) elevations, (iii) positions within any applicable Facility module or component, (iv) location within the Job Site, (v) accessibility, (vi) constraints of the work permit system and Commissioning activities or (vii) and any other factor that would affect productivity in the completion of the applicable Work, including Work executed on transportation barges;

 

  (p)

Contractor and Subcontractor cost of construction equipment, including equipment on standby as defined in the Facility equipment plan and equipment for Pre-Commissioning, Commissioning and start-up at the Job Site, required to perform the Reimbursable Work. Owner approval shall be required for the Facility equipment plan and any stand-by other than short term stand-by of equipment; when stand-by is not approved then demobilization and remobilization costs shall be applicable. All Contractor owned equipment shall be charged at the rates set forth in Exhibit C. Construction equipment charges shall be consistent with the following:

 

3


Execution Version

 

  (1)

mobilization and demobilization expenses (including unavoidable cancellation charges from Subcontracts upon termination) will be charged to Owner at the cost incurred by Contractor for equipment in the Mobilization Plan that is approved by Owner (such approval not to be unreasonably withheld);

 

  (2)

each of (i) tires and tracks using the rates set forth in Exhibit C, (ii) labor and materials for long-term maintenance repairs and other service and repairs, and (iii) fuel, oil, and grease;

 

  (3)

Operators are not included in the stated rates for equipment;

 

  (4)

Third party rentals will be invoiced at cost;

 

  (5)

equipment will not be overhauled/painted prior to removal from the Job Site; and

 

  (6)

Contractor equipment assigned to the Work will be charged to Owner, and shall not exceed 50 hours per week for the first shift unless approved by Owner. Equipment utilized on the approved equipment plan on a second shift shall be billed shall not exceed 20 hours per week unless approved by Owner. To the extent that equipment is equipped with a smart meter that shows actual utilization, and the meter shows utilization of hours in excess of 50 hours for day shift and 20 hours for night shift if assigned, the equipment will be billed based on the actual meter hours. Equipment that is expected to have smart meters includes but not is limited to cranes, dozers, back hoes, roller/vibrators. Equipment charges apply to equipment which is verifiable and documented that is on standby for Work, Owner shall be notified weekly of all equipment on stand-by. To the extent the Contractor decides to pre-stage equipment prior to use, mobilizes equipment without prior Owner authorization, or equipment is stored on the Job Site prior to removal, neither storage nor equipment utilization will be invoiced. Contractor shall notify Owner of all pre-stage or stored equipment on the Job Site. Contractor shall provide a copy of the approved Mobilization Plan, proof of equipment utilization in the form of weekly equipment utilization summary timesheets signed by authorized Owner personnel for all equipment utilized. In the event equipment is approved for standby by Owner, equipment charges, as set forth in Exhibit C, shall apply. In order to substantiate equipment charges in Contractor’s invoice, Contractor shall provide proof of standby authorization, and provide weekly summary timesheet signed by Company authorized personnel for all equipment on standby.

 

  (q)

commodities, supplies, rental tools, loss or damage to tools not included with ST&S, re-assembly of equipment after inspections or transportation, consumables, skip boxes, scaffolding replacement components, Connex and freight containers, and personnel protective equipment;

 

4


Execution Version

 

  (r)

costs of commercial testing and inspection laboratories, soils testing and analysis consultants, x-ray testing/NDE/NDT, concrete and soil testing, stress relieving kits and supplies, etc. and similar third-party services required for the performance of the Reimbursable Work;

 

  (s)

rental costs for vehicles for Contractor personnel necessary for the performance of the Reimbursable Work, only if such rental costs were incurred in compliance with Contractor’s vehicle rental policy, Owner’s Standards and per Owner’s prior approval with respect to any changes to the vehicle rental policy or equipment plan. Aggregate rental costs for any vehicle shall not exceed the vehicle’s fair market value;

 

  (t)

Hazardous Substance cleanup, subject to the limitations set forth in Section 3.8.46 and Section 30.1.2 of the Agreement;

 

  (u)

miscellaneous Job Site expenses necessary to perform the Reimbursable Work, including expenses to acquire, purchase, lease or pay for furniture, phones, copiers, printers, plotters, facsimile equipment, mail service, internet service, computers, training materials and equipment, networks, courier services, internal and external photocopying, related petty cash items, temporary facilities and supplies, utilities, miscellaneous Job Site services, specialty software requested by Owner or not normally used by Contractor and software maintenance (so long as notified to Owner prior to use);

 

  (v)

Facility-specific entertainment and incentives consistent with Contractor policies, with any expense exceeding [***] per event requiring Owner’s prior approval;

 

  (w)

consumable spares and fluid fills of lubricants, all liquids and chemicals such as catalysts, chemicals, water, nitrogen, coolants, greases, lubricants, refrigerants and any topping off of these items and similar supplies, in each case required for construction, Pre-Commissioning, Commissioning and start-up;

 

  (x)

Safety supplies and equipment (including PPE) for the Reimbursable Work;

 

  (y)

costs incurred in replacing operating and Commissioning Spare Parts borrowed from Owner’s inventory (excluding Spare Parts used in connection with Corrective Work);

 

  (z)

costs incurred in obtaining and maintaining Facility-specific insurance policies required under the Agreement;

 

  (aa)

costs of Facility-specific project attorney personnel hours and expenses as well as external attorney and claims consultant costs (specifically including for Subcontractor and Agent For Contractor claims) incurred by Contractor while performing the Reimbursable Work as provided for in Section 23.1.4 of the Agreement, but excluding attorney hours and expenses attendant to any dispute between Owner and Contractor/Guarantor arising under the Agreement or the Contractor Guarantee;

 

5


Execution Version

 

  (bb)

costs to provide the Performance and Payment Bonds to Owner required under Section 9.2.1 of the Agreement;

 

  (cc)

costs incurred by Contractor for Permitted Liens;

 

  (dd)

uninsured losses and deductibles described in the Agreement; and

 

  (ee)

costs associated with Subcontractor and Agent For Contractor change orders and claims including all settlement amounts, as provided for in Section 23.1.4 of the Agreement, to the extent not addressed in clause (aa).

Notes:

1. If there is no applicable rate contained in Exhibit C to the Agreement for any item, then a new rate shall be agreed by pro-rating, extrapolating or interpolating from rates for similar work contained within Exhibit C to the Agreement. Should there be no similar items, a new rate shall be calculated from analysis agreed between Owner and Contractor based on similar labor productivity to that in the rates in Exhibit C to the Agreement. The Contractor shall provide sufficient detail to demonstrate that the labor productivity used for new rates is compatible with those used in the Agreement. Once agreed, the new rates shall remain valid for the duration of one year and be adjusted yearly thereafter in accordance with Exhibit C.

2. In the event Contractor incurs a Direct Cost in a currency other than Dollars, Contractor shall convert the amount of such Direct Cost to Dollars using the official rate of foreign exchange between such currency and the Dollar published by the central bank or comparable national monetary authority of the jurisdiction to which such other currency relates on the Business Day immediately preceding the day on which such Direct Cost is invoiced to Owner in a Request for Payment. Contractor shall include details of the calculation of such rate of foreign exchange together with the relevant Request for Payment. In no event shall Owner be responsible for Contractor’s foreign exchange hedging costs or other currency hedges except to the extent approved in accordance with clause (j) above.

 

2.

Non-Reimbursable Costs.

Non-Reimbursable Costs include costs or expenses incurred by Contractor related to the following items:

 

  (a)

Taxes based on or related to the net income, capital or net worth of Contractor or any Subcontractor;

 

6


Execution Version

 

  (b)

costs and expenses incurred in connection with corporate training recruiting and corporate meetings not directly related to the Work, or public and/or business relations not directly related to the Work;

 

  (c)

Liquidated damages required to be paid under the Agreement;

 

  (d)

Amounts required to be paid under Section 5.1.2, Section 30.1.2 or Section 40.3.2 of the Agreement;

 

  (e)

Any costs, expenses or other items included in Contractor’s G&A as listed in Section 3 below;

 

  (f)

Any additional general and administrative expenses, fees or mark-up of a Contractor Affiliate;

 

  (g)

Sales and use taxes on construction equipment and Contractor’s machinery, materials and other equipment to the extent not constituting a Direct Cost;

 

  (h)

Owner Costs and Direct Costs for Indemnified Liens;

 

  (i)

Owner Costs and Direct Costs to discharge and settle Subcontractor and Agent For Contractor claims arising from and solely attributable to the Gross Negligence or Willful Misconduct of Senior Supervisory Personnel;

 

  (j)

Costs, fees and expenses incurred by Contractor or required to be paid to Owner to the extent of Contractor’s obligations under Sections 30.1.1, 30.1.2 and 30.1.3 of the Agreement;

 

  (k)

Amounts required to be paid by Contractor under Section 31.3 of the Agreement, it being understood that such amounts shall not be treated as a Non-Reimbursable Cost for the purposes of Section 21.1(e) of the Agreement;

 

  (l)

incidental, indirect, punitive or consequential damages or for loss of profit, product, revenue, contract or use to the extent waived by Owner pursuant to Section 21.2 of the Agreement;

 

  (m)

Corrective Work performed during any Warranty Period in respect of which Substantial Completion was achieved prior to termination;

 

  (n)

costs and expenses of any work outside the Scope of Work described in Exhibit A of the Agreement that was performed by Contractor prior to its having received an executed Change Order or authorization from Owner;

 

  (o)

costs and expenses of performing that portion of the Work that Contractor knows to be a violation to any Laws or Permits;

 

7


Execution Version

 

  (p)

Contractor’s repayment to Owner of amounts previously paid by Owner under this Agreement that were determined to be a Non-Reimbursable Cost;

 

  (q)

costs and expenses incurred by Contractor in connection with Section 30.1.1 of the Agreement;

 

  (r)

costs of attorney hours and expenses attendant to any dispute between Owner and Contractor/Guarantor arising under the Agreement or the Contractor Guarantee;

 

  (s)

the amount of any arbitral award rendered in favor of Owner under Section 36.1.3 of the Agreement and the costs of such arbitration to the extent it is determined by the tribunal that Contractor should be responsible for such costs; it being understood that such amounts shall not be treated as a Non-Reimbursable Cost for the purposes of Section 21.1(e) of the Agreement;

 

  (t)

Contractor’s capital or financing costs, including principal or interest on capital used for performance of the Work;

 

  (u)

Amounts that Contractor is obligated to reimburse to Owner specified within the Agreement;

 

  (v)

charitable contributions, unless approved in advance by Owner;

 

  (w)

Contractor’s costs incurred to achieve the “make good” obligations under Section 15.3.4 of the Agreement, except as provided in Section 15.3.4 of the Agreement;

 

  (x)

any cost or expense described in Section 1 that (1) is not auditable and verifiable by Contractor’s accounts and records or (2) was improperly incurred without Owner’s approval where required;

 

  (y)

any cost or expense paid to a Subcontractor that was not due and owing to such Subcontractor in accordance with the express terms of the relevant Subcontract or this Agreement; and

 

  (z)

per-occurrence costs or expenses exceeding one thousand Dollars ($1000) incurred by Contractor or any Subcontractor for dinners, lunches, social events or team building event, to the exent not approved by Owner.

 

3.

Contractor’s G&A

A multiplier of [***] (the “G&A Multiplier”) will be applied across all Direct Costs for G&A recovery. The G&A Multiplier will recover the following overhead costs:

 

  a)

Home Office Executive Management

 

  b)

Corporate Equipment Administration

 

  c)

Marketing

 

  d)

Corporate Accounting/Financial Reporting/Financial Analysis

 

8


Execution Version

 

  e)

Corporate Risk Management Staff

 

  f)

Human Resources (excluding Facility assigned Human Resources staff)

 

  g)

Corporate Tax Staff (unless addressing Owner tax benefits)

 

  h)

Corporate I/T Staff and I/T Infrastructure

 

  i)

Corporate Treasury/Cash Management

 

  j)

Internal Audit

 

  k)

Corporate Training and Corporate Events

 

  l)

Division and District Managers

 

  m)

Corporate Legal Staff (non Facility-specific)

 

  n)

Employee Benefit Administration

 

  o)

Corporate offices and Corporate vehicles

 

  p)

Corporate telecommunications and computer hardware

 

  q)

Corporate Software and licenses

In no event shall the G&A Multiplier apply to any general and administrative expenses, fees or mark-up of a Contractor Affiliate.

 

9


Execution Version

 

EXHIBIT B-2

TARGET PRICE COMPONENTS

 

Direct Costs:

   $ [***

Agent For Contracts Costs:

   $ [***

Contractor’s G&A:

   $ [***

Contractor’s Margin:

   $ [***
  

 

 

 

Target Price:

   $ [***

 

1


Execution Version

 

EXHIBIT B-3

COVER COSTS EXAMPLES

[Omitted]

 

1


Execution Version

 

EXHIBIT B-4

PAYMENT PROCEDURES

[Omitted]

 

1


 

Attachment C-1

HOUSTON OPERATING CENTER

[Omitted]


 

Attachment C-2

MODULE YARD STAFF

[Omitted]


 

Attachment C-3

SITE STAFF RATES

[Omitted]


 

Attachment C-4

INDICATIVE CONSTRUCTION EQUIPMENT RENTAL RATES

[Omitted]


 

Attachment C-5

CRAFT LABOR RATES

[Omitted]


 

Attachment C-6

Other Direct Costs

[Omitted]


 

Attachment C-7

Other Direct Costs

[Omitted]


Execution Version

 

EXHIBIT D

SCHEDULE MILESTONES

[Omitted]

 

1


Execution Version

 

EXHIBIT E

PROJECT SCHEDULE

[Omitted]

 

1


Execution Version

 

EXHIBIT F-1

FORM OF CONTRACTOR CERTIFICATE FOR PARTIAL WAIVER OF LIENS

[Omitted]


Execution Version

 

EXHIBIT F-2

FORM OF SUBCONTRACTOR CERTIFICATE FOR PARTIAL WAIVER OF LIENS

[Omitted]


Execution Version

 

EXHIBIT F-3

FORM OF CONTRACTOR CERTIFICATE FOR FINAL WAIVER OF LIENS

[Omitted]


Execution Version

 

EXHIBIT F-4

FORM OF SUBCONTRACTOR CERTIFICATE FOR FINAL WAIVER OF LIENS

[Omitted]


Execution Version

 

EXHIBIT F-5

FORM OF CONSENT AND AGREEMENT

[Omitted]


 

EXHIBIT F-6A

[Intentionally Omitted]

 

23


 

EXHIBIT F-6B

[Intentionally Omitted]

 

24


 

EXHIBIT F-7

FORM OF REQUEST FOR PAYMENT

[Omitted]

 

25


 

EXHIBIT F-8

FORM OF LIMITED NOTICE TO PROCEED

[Omitted]

 

29


 

EXHIBIT F-9A

PERFORMANCE BOND

[Omitted]

 

32


 

EXHIBIT F-9B

FORM OF PAYMENT BOND

[Omitted]

 

33


 

EXHIBIT F-10

FORM OF CHANGE ORDER

[Omitted]

 

37


 

EXHIBIT F-11

FORM OF LNG PRODUCTION SYSTEM

MECHANICAL COMPLETION CERTIFICATE

[Omitted]

 

41


 

EXHIBIT F-12

FORM OF LNG PRODUCTION SYSTEM RFSU CERTIFICATE

[Omitted]

 

44


 

EXHIBIT F-13

FORM OF NOTICE TO PROCEED

[Omitted]

 

46


 

EXHIBIT F-14

FORM OF TITLE INSURANCE INDEMNITY AGREEMENT

[Omitted]

 

48


 

EXHIBIT F-15

FORM OF PAYMENT STATUS AFFIDAVIT

[Omitted]

 

50


 

EXHIBIT F-16

FORM OF SUBCONTRACTOR’S PAYMENT STATUS AFFIDAVIT

[Omitted]

 

52


Execution Version

 

EXHIBIT G

TRAINING REQUIREMENTS

[Omitted]

 

1


Execution Version

 

EXHIBIT H

SCHEDULE OF MAJOR VENDORS

[Omitted]

 

1


Execution Version

 

EXHIBIT I

PROGRESS REPORTING AND PROJECT MEETINGS

[Omitted]


Execution Version

 

EXHIBIT J

DOCUMENT CONTROL AND INFORMATION MANAGEMENT

[Omitted]

 

1


Execution Version

 

EXHIBIT K

LIST OF CONTRACTOR’S KEY PERSONNEL

[Omitted]


Execution Version

 

EXHIBIT L

PERMITS, LICENSES AND GOVERNMENT APPROVALS

[Omitted]

 

1


Execution Version

 

EXHIBIT M

RELIED UPON INFORMATION

[Omitted]

 

1


 

EXHIBIT N

OWNER SUPPLIED INFORMATION

[Omitted]


Execution Version

 

EXHIBIT O

SCHEDULE OF MAJOR SUBCONTRACTORS

[Omitted]

 

1


Execution Version

 

EXHIBIT P

MECHANICAL COMPLETION, COMMISSIONING, START-UP AND

SUBSTANTIAL COMPLETION

[Omitted]

 

1


Execution Version

 

EXHIBIT Q

OWNER PERSONNEL

[Omitted]


Execution Version

 

EXHIBIT R

DEMONSTRATION TESTS AND PERFORMANCE TESTS

[Omitted]

 

1


Execution Version

 

EXHIBIT S

LNG PRODUCTION SYSTEM HANDOVER PACKAGES

[Omitted]

 

1


Execution Version

 

EXHIBIT T

REQUIREMENTS FOR SIMULTANEOUS OPERATIONS

[Omitted]

 

1


Execution Version

 

EXHIBIT U

HEALTH, SAFETY, SECURITY AND ENVIRONMENTAL REQUIREMENTS

[Omitted]

 

1


Execution Version

 

EXHIBIT V

FIRST FILLS AND CATALYSTS

[Omitted]

 

1


Execution Version

 

EXHIBIT W

OPEN COST ITEMS

[Omitted]

 

1


 

Execution Version

EXHIBIT X

COST OVERRUN AND COST SAVING ADJUSTMENTS

The purpose of this Exhibit is to describe the process for calculating the amount of any adjustment to the cost overrun and cost saving values in Section 8.2 and Section 8.3 of the Agreement, respectively (the “Values”), on the basis of any changes in the cost of labor, materials and equipment if Notice to Proceed Date occurs after [***]. This Exhibit X does not address the adjustments to the Project Schedule that may be required under Section 4.1.4 of the Agreement.

Adjustment Principles

 

   

The Values will be increased or decreased depending on the total changes to the cost of staff, labor, materials and equipment determined pursuant to this Exhibit X. A Cost Increase (as defined below) will result in an increase to the Values in Section 8.2 of the Agreement and a decrease to the Values in Section 8.3 of the Agreement. Conversely, a Cost Decrease (as defined below) will result in a decrease to the Values in Section 8.2 of the Agreement and an increase to the Values in Section 8.3 of the Agreement.

 

   

If the Notice to Proceed Date occurs after [***], Contractor shall conduct a complete review of the impacts to all staff, labor, materials and equipment components of the Direct Cost between [***] and the Notice to Proceed Date, following the procedures described below.

 

   

The maximum decrease to each Value in Section 8.2.1 of the Agreement and the maximum increase to each Value in Section 8.3.1 of the Agreement is [***].

 

   

If the Cost Increase or Cost Decrease is determined to be less than [***], the Values shall not be adjusted.

Method of Calculation

Contractor shall evaluate the impacts to all staff, labor, materials and equipment components of the Direct Cost between [***] and the Notice to Proceed Date and adjust the values of such components, positive or negative, as follows:

 

   

Contractor shall, where practicable, update the equipment pricing and deliveries. The technical specification of the equipment is to remain unchanged. Bid updates will be used when available. If priced internally, Contractor is to re-evaluate prices based on the current market conditions relative to in-house metrics as defined by agreed indices described below.

 

   

Materials pricing shall be adjusted by the percentage change in the relevant commodity reflected in the London Metal Exchange (available at www.lme.com) or IHS Markit.

 

1


 

Execution Version

 

   

Labor total craft compensation (wage rate, per diem, etc.) components shall be adjusted utilizing data from Alpha Resources, LLC (Gulf Coast region).

 

   

Staff total compensation shall be adjusted utilizing data to be mutually agreed between the Parties.

Contractor shall aggregate all adjustments described above to calculate a total increase or decrease in the staff, labor, materials and equipment components of the Direct Cost since [***]. An amount equal to [***] reflecting the escalation factor in the Target Price calculation shall be deducted from such total increase or decrease to yield the “Cost Increase” or “Cost Decrease”, as applicable.

Procedure

 

   

Within [***] days following the Notice to Proceed Date, Contractor shall submit to Owner its calculation of Cost Increase or Cost Decrease based on the method set forth above, together with reasonably detailed supporting documentation and agreed to invoices specified above.

 

   

Within [***] days following its receipt of Contractor’s calculations, Owner shall either accept or reject such calculations, stating the reasons for any rejection and providing any calculations in support of such rejection. If Owner accepts Contractor’s calculations, the Parties shall, subject to the principles set forth above, enter into an amendment to the Agreement to adjust the Values by an amount equal to one hundred percent of the Cost Increase or the Cost Decrease, as applicable.

 

   

If Owner rejects Contractor’s calculations, then within [***] days following its receipt of Owner’s rejection, Contractor shall either accept Owner’s calculations or reject such calculations and submit the matter for expert determination under the Agreement.

Examples

 

  1.

Contractor’s calculations result in a Cost Increase of [***]. Owner agrees with such calculations. The Agreement is amended to increase each Value in Section 8.2 of the Agreement by an amount equal to [***] and decrease each Value in Section 8.3 of the Agreement by an amount equal to [***].

 

  2.

Contractor’s calculations result in a Cost Decrease of [***]. Owner agrees with such calculations. The Agreement is amended to decrease each Value in Section 8.2 of the Agreement by an amount equal to [***] and increase each Value in Section 8.3 of the Agreement by [***].

 

2


 

Execution Version

EXHIBIT Y

COORDINATION PROCEDURE

[Omitted]

 

1


 

Execution Version

EXHIBIT Z

PHASE II TARGET PRICE ALIGNMENT

[Omitted]

 

1

Exhibit 10.3

Execution Version

GUARANTY

This GUARANTY, dated as of April 21, 2021 (this “Guaranty”), is made by KBR, INC., a Delaware corporation (“Guarantor”), for the benefit of VENTURE GLOBAL PLAQUEMINES LNG, LLC, a Delaware limited liability company (the “Beneficiary”). The Guarantor and Beneficiary are referred to herein individually as a “Party” and collectively as the “Parties”.

RECITALS

WHEREAS, the execution and delivery of this Guaranty is required pursuant to section 9.3 of that certain Amended and Restated Engineering, Procurement and Construction Agreement (as may be amended, modified or supplemented from time to time, the “Agreement”), dated as of the date hereof, by and between KZJV LLC, a Texas limited liability company (“Obligor”) and Beneficiary;

WHEREAS, this Guaranty is entered into by the Guarantor as an inducement for Beneficiary to enter into and consummate the transactions contemplated by the Agreement; and

WHEREAS, Guarantor will derive substantial benefit from the consummation of the transactions contemplated by the Agreement.

NOW, THEREFORE, in consideration of the mutual covenants contained herein and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Guarantor and Beneficiary agree as follows:

ARTICLE 1

DEFINITIONS AND CONSTRUCTION

1.1 Definitions. All capitalized terms used but not defined herein shall have the meanings set forth for such terms in the Agreement.

ARTICLE 2

GUARANTY

2.1 Guaranty. Guarantor hereby irrevocably, absolutely, fully and unconditionally guarantees to Beneficiary and its successors and assigns the timely and complete payment and performance when and as due (whether at the stated due date, by acceleration or otherwise) of all obligations of Obligor arising under the Agreement (the “Guaranteed Obligations”), subject to the limitations and rights of Obligor set forth in the Agreement.


 

2.2 No Release or Discharge. This Guaranty is a direct and primary obligation of Guarantor and shall be an irrevocable, unconditional, absolute and continuing guaranty, irrespective of the following potential defenses:

2.2.1 any invalidity, voidability or unenforceability of, or defect or deficiency applicable to Obligor in respect of, the Agreement or any other documents executed in connection with the Agreement based on Obligor’s lack of corporate power and authority to enter into the Agreement or such other documents or the failure of the Agreement or such other documents to be duly authorized and executed by Obligor and its signatories;

2.2.2 any postponement or extension of the date on which any payment must be made pursuant to the Agreement or postponement or extension of the date on which any act must be performed by Obligor thereunder, provided that any such postponement or extension shall be deemed to apply to the Guarantor’s obligations hereunder in the same way that it applies to Obligor’s obligations under the Agreement;

2.2.3 whether or not Guarantor received direct notice of or consented to any modification, amendment, supplement, renewal or waiver of the Agreement or any of the terms or conditions of the Agreement, including under a Change Order, provided that the Guaranteed Obligations shall not be greater than the obligations of Obligor under the Agreement, as the Agreement may be so modified, amended, supplemented, renewed or waived without Guarantor’s consent;

2.2.4 any failure, omission or delay on the part of Beneficiary or any other Person to confirm or comply with any of the terms or conditions of the Agreement or any other documents executed in connection with the Agreement;

2.2.5 except as to applicable statutes of limitation or other contractual period of limitation, the failure, omission, delay, or refusal by Beneficiary to exercise against Obligor, in whole or in part, any right or remedy held by Beneficiary with respect to the Agreement;

2.2.6 any legal disability of Guarantor, or any release or discharge of Guarantor by a bankruptcy court;

2.2.7 any stay applicable to any enforcement of the Guaranteed Obligations against Obligor;

2.2.8 any rights of subrogation, reimbursement, indemnity or contribution that Guarantor or Beneficiary may have against Obligor;

2.2.9 any lack of knowledge by Guarantor as to the condition (including financial) of Obligor, since Guarantor shall be responsible for obtaining its own knowledge of such condition;

2.2.10 any election of remedies by Beneficiary, even if such election of remedies impairs or destroys Guarantor’s right of subrogation against Obligor;

2.2.11 any merger, consolidation, termination of or change in corporate existence, structure or ownership of Obligor, any JV Member or Guarantor, or any insolvency, bankruptcy, reorganization or other similar proceeding affecting Obligor, and JV Member or its assets;

 

2


 

2.2.12 any amendment, termination or material breach of, or any dispute, claim, litigation or arbitration arising under, the JV Agreement; or

2.2.13 subject to the defenses available to Guarantor pursuant to Section 2.6.2, any other occurrence or circumstance which might otherwise constitute a legal or equitable discharge or defense of a guarantor or which might otherwise limit recourse against Guarantor all without notice to or further assent by Guarantor, who shall remain bound by this Guaranty, which shall remain in full force and effect until all of the Guaranteed Obligations have been paid in full or otherwise extinguished.

No action which Beneficiary shall take or fail to take in connection with the Guaranteed Obligations, nor any course of dealing with Obligor or any other person, shall release Guarantor’s obligations hereunder, affect this Guaranty in any way, or afford Guarantor any recourse against Beneficiary. This Guaranty is in no way conditioned or contingent upon any attempt to collect from or enforce performance or payment by Obligor or upon any other event, contingency or circumstance whatsoever. Beneficiary shall not be obligated to take any action, obtain any judgment or file any claim prior to enforcing this Guarantee. Beneficiary shall not be obligated to file any claim relating to the Obligations in the event that Obligor becomes subject to a bankruptcy, reorganization or similar proceeding, and the failure of Beneficiary to so file shall not affect Guarantor’s obligations hereunder.

This Guaranty shall continue to be effective or be reinstated, as the case may be, if at any time any payment of any of the Guaranteed Obligations are annulled, set aside, invalidated, declared to be fraudulent or preferential, rescinded or must otherwise be returned, refunded or repaid by Beneficiary upon the insolvency, bankruptcy, dissolution, liquidation or reorganization of Obligor or any other guarantor, or upon or as a result of the appointment of a receiver or conservator of, or trustee for Obligor or any other guarantor or any substantial part of its property or otherwise, all as though such payment or payments had not been made.

2.3 Waiver of Rights. Subject to the limitations expressly set forth in this Guaranty, Guarantor understands and agrees that the guaranty contained in Section 2.1 shall be a continuing guaranty. Guarantor hereby expressly waives:

2.3.1 notice of acceptance of this Guaranty, of the creation or existence of any of the Guaranteed Obligations, of any of the matters described in Section 2.2 and of any action by Beneficiary in reliance hereon or in connection herewith;

2.3.2 notice of the entry into the Agreement between Obligor and Beneficiary and of any amendments, supplements or modifications thereto; or any waiver of consent under the Agreement, including waivers of the payment and performance of the obligations thereunder;

 

 

3


 

2.3.3 notice of any increase, reduction or rearrangement of Obligor’s obligations under the Agreement or any extension of time for the payment of any sums due and payable to Beneficiary under the Agreement;

2.3.4 presentment, demand for payment, notice of acceptance, notice of dishonor or nonpayment, protest and notice of protest or any other notice with respect to the Guaranteed Obligations; and

2.3.5 any requirement that suit be brought against, or any other remedy or action by Beneficiary be taken against, or any notice of default or other notice be given to, or any demand be made on Obligor or any other person, or that any other action be taken or not taken as a condition to Guarantor’s liability for the Guaranteed Obligations under this Guaranty or as a condition to the enforcement of this Guaranty against Guarantor.

2.4 No Subrogation. Guarantor will not exercise and irrevocably agrees to waive any rights against Obligor which it may acquire by way of subrogation, reimbursement, exoneration, contribution or indemnification in connection with this Guarantee by any payment made hereunder or otherwise, until all Guaranteed Obligations shall have been fully and indefeasibly paid and performed. If (a) Guarantor makes payment to Beneficiary of all or any part of the Guaranteed Obligations and (b) all of the then outstanding Guaranteed Obligations shall have been paid in full, Beneficiary shall, at Guarantor’s request, execute and deliver to Guarantor documents to evidence the transfer by subrogation to Guarantor of any interest in the Guaranteed Obligations resulting from such payment by Guarantor. If any amount shall be paid to Guarantor on account of such subrogation, contribution, reimbursement or indemnity rights at any time when all of the Guaranteed Obligations and all amounts owing hereunder shall not have been performed and paid in full, such amount shall be held by Guarantor in trust for Beneficiary, segregated from other funds of Guarantor, and shall, forthwith upon receipt by Guarantor, be turned over to Beneficiary in the exact form received by Guarantor (duly endorsed by Guarantor to Beneficiary, if required), to be applied against the Guaranteed Obligations, whether or not matured, in such order as Beneficiary may determine.

2.5 Demand and Payment. Beneficiary may provide written notice to Guarantor pursuant to Section 5.1 at any time if Obligor fails to punctually pay or perform any of the Guaranteed Obligations. There are no other requirements of notice, presentment or demand. Guarantor shall pay, or cause to be paid, such Guaranteed Obligations within five (5) Business Days of receipt of such notice, unless, within such period, the default giving rise to such notice has been remedied. If Beneficiary is prevented from making a demand on Guarantor as a result of any applicable Law, any injunction, order or other action of any court or other Government Authority or any stay, moratorium or other action in any bankruptcy, insolvency or other similar proceeding, Guarantor shall not be excused from paying and performing its obligations under this Guaranty as and when due. All payments by Guarantor hereunder shall be paid without setoff or deduction in U.S. dollars in immediately available funds to such accounts as may be designated by Beneficiary from time to time. Guarantor agrees to pay on demand all fees and out of pocket expenses (including the reasonable fees and expenses of Beneficiary’s counsel) in any way relating to the enforcement or protection of the rights of Beneficiary hereunder. Any amount due and payable here under shall, if not paid when due, accrue interest at the Late Payment Rate from the date such payment was due until the date such payment is made in full.

 

4


 

2.6 Primary Liability of Guarantor; Guarantor’s Defense.

2.6.1 Guarantor agrees that Beneficiary may enforce this Guaranty without the necessity at any time of resorting to or exhausting any other security or collateral, including any other Contractor Guarantee provided by any other Contractor Guarantor, or exercising or exhausting any other remedies against Obligor or any other Contractor Guarantor. This is a guaranty of payment and performance when and as due and not merely of collection.

2.6.2 Notwithstanding anything to the contrary stated herein or in the Agreement or any documents related thereto, Guarantor’s undertakings and obligations hereunder with respect to the Agreement are derivative of and not in excess of Obligor’s obligations under the Agreement and Guarantor may assert as a defense, right of set-off or counterclaim to its obligations hereunder any defense, right of set-off or counterclaim that Obligor may have to such Guaranteed Obligations under the Agreement or otherwise, even if Obligor fails to raise the same, except (i) a defense based on the discharge of the Guaranteed Obligations as to Obligor in a bankruptcy or insolvency proceeding or (ii) other defenses expressly waived hereunder.

2.7 Continuing Guaranty. Guarantor’s obligations under Section 2.1 of this Guaranty shall continue in force and effect until the Guaranteed Obligations have been fully performed or otherwise extinguished under the Agreement, at which time this Guaranty and all of Guarantor’s obligations hereunder shall terminate and expire. Guarantor agrees that any judgment between Obligor and Beneficiary under the Agreement (whether in contested litigation or arbitration or otherwise) shall be conclusive and binding on Guarantor for the purposes of determining Guarantor’s obligations under this Guaranty.

ARTICLE 3

REPRESENTATIONS AND WARRANTIES

3.1 Representations and Warranties of Guarantor. Guarantor represents and warrants as follows:

3.1.1 It is a corporation, duly formed, validly existing and 111 good standing under the laws of the State of Delaware.

3.1.2 It has all requisite power and authority to execute and deliver this Guaranty and to perform all obligations to be performed by it hereunder. The execution and delivery of this Guaranty and the consummation of the transactions contemplated hereby have been duly and validly authorized and approved by all requisite corporate action on its part. This Guaranty has been duly and validly executed and delivered by it and this Guaranty constitutes a valid and binding obligation of it, enforceable against it in accordance with its terms.

 

 

5


 

3.1.3 The execution and delivery of this Guaranty by it and the performance of its obligations hereunder by it do not and shall not: (i) violate any applicable Law or require any filing with, consent, approval or authorization of, or notice to, any Government Authority or any other Person, except as otherwise obtained prior to the date hereof, (ii) violate any of its organizational documents or (iii) breach or conflict with any material contract to which it is a party or by which it may be bound, result in the termination of any such material contract, result in the creation of any lien upon any of its assets or constitute an event which, after notice or lapse of time or both, would result in any such breach, termination or creation of a lien upon any of its assets.

ARTICLE 4

COVENANTS

4.1 Guarantor Financial Statements. As soon as available, but in any event within sixty (60) Days after the end of the first three fiscal quarters of the Guarantor, Guarantor shall make available to Obligor for delivery to Beneficiary the unaudited and consolidated balance sheet of the Guarantor, as of the end of such quarter, the related consolidated statements of income, cash flows, and retained earnings and stockholders’ equity for such quarter, all of which shall be certified by the chief financial officer or equivalent officer of the Guarantor subject to normal year-end audit adjustments. As soon as available, but in any event no later than one-hundred twenty (120) Days after the end of each fiscal year of the Guarantor, Guarantor shall deliver to Beneficiary a copy of the audited consolidated balance sheets at the end of each such year as well as the related consolidated statements of income, retained earnings, and cash flows for such year.

4.2 Joint Venture. Guarantor shall not, and shall cause the JV Member with whom it is Affiliated not to, in each case without the prior written consent of Beneficiary:

4.2.1 amend or modify the JV Agreement in a manner that would cause the representation of Obligor set forth in section 28.2.9 of the Agreement, if repeated as of such time, to be materially inaccurate or misleading in any respect;

4.2.2 assign, sell, transfer, encumber (other than under the JV Agreement) or convey its ownership interests in Obligor to any Person other than its wholly-owned Affiliate or the other JV Member in accordance with the JV Agreement;

4.2.3 amend or modify the division of responsibilities between the JV Members in the JV Agreement in a manner that would be materially inconsistent with the division of responsibilities set forth in exhibit A to the Agreement;

4.2.4 amend, modify or waive any of its “step-in” rights under the JV Agreement; or

4.2.5 permit Obligor to engage in any business other than the performance of the Agreement and such other activities as are incidental thereto.

 

6


 

4.3 Maintainance of Existence. Guarantor shall, and shall cause the JV Member with whom it is Affiliated to, cause Obligor to preserve, renew and keep in full force and effect its organizational existence and good standing in its jurisdiction of formation and maintain and renew all of the powers, licenses, rights, privileges and franchises necessary for its performance of the Agreement and in the normal conduct of its business. Guarantor shall not, and shall cause JV Member with whom it is Affiliated not to, seek or voluntarily consummate any liquidation, bankruptcy, dissolution or reorganization of Obligor.

4.4 Notice of Disputes. Guarantor shall provide prompt written notice to Beneficiary of any material dispute, claim, litigation, arbitration or other proceeding arising under the JV Agreement.

4.5 No Restriction. Neither Guarantor nor any of its Affiliates shall agree or become subject to any restriction, contractual or otherwise, that would prohibit it or any of its Affiliates from bidding for or entering into a contract or guarantee, as applicable, in respect of the second ten (10) MTPA (nameplate) phase of the Plaquemines LNG export project under development by Beneficiary and its Affiliates, unless Beneficiary’s prior written approval of such restriction is obtained.

ARTICLE 5

MISCELLANEOUS

5.1 Notices. All notices and other communications required or permitted to be given by any provision of this Guaranty shall be in writing and mailed (certified or registered mail, postage prepaid, return receipt requested) or sent by hand or overnight courier, or by facsimile transmission (with acknowledgment received), charges prepaid and addressed to the intended recipient as follows, or to such other addresses or numbers as may be specified by a Party from time to time by like notice to the other parties:

If to Guarantor, at:

If to Beneficiary, at:

 

 

7


 

All notices and other communications given in accordance with the provisions of this Guaranty shall be deemed to have been given and received: (i) when delivered, if delivered by hand or transmitted by facsimile (with acknowledgment received); (ii) five (5) Business Days after the same are sent by certified or registered mail, postage prepaid, return receipt requested; or (iii) one (I) Business Day after the same are sent by a reliable overnight courier service, with acknowledgment of receipt.

5.2 Assignment. This Guaranty shall be binding upon and inure to the benefit of the Parties and their respective successors and permitted assigns. Neither Party may assign (by contract, stock sale, operation of law or otherwise) either this Guaranty or any of its rights, interests, or obligations hereunder without the express prior written consent of the other Party, and any attempted assignment, without such consent, shall be null and void; provided, however that Beneficiary may assign this Agreement, without the consent of Guarantor (but with written notice to Guarantor) in connection with (i) an assignment of the Agreement by Beneficiary permitted under the Agreement or (ii) a collateral assignment of this Guaranty by Beneficiary to any Lender.

5.3 Rights of Third Parties. Nothing expressed or implied in this Guaranty is intended or shall be construed to confer upon or give any Person, other than Beneficiary, any right or remedies under or by reason of this Guaranty.

5.4 Entire Agreement. This Guaranty constitutes the entire agreement between the Parties with respect to the subject matter hereof and supersedes any prior understandings, negotiations, agreements, or representations between the Parties of any nature, whether written or oral, to the extent they relate in any way to the subject matter hereof.

5.5 Counterparts. This Guaranty may be executed in any number of counterparts, each of which shall be deemed an original but all of which together will constitute one and the same instrument.

5.6 Amendments. This Guaranty may be amended or modified in whole or in part, and terms and conditions may be waived, only by a duly authorized agreement executed by Guarantor and Beneficiary which makes reference to this Guaranty.

5.7 Severability. If any provision of this Guaranty or the application of any such provision to any Person or circumstance shall be declared by any court of competent jurisdiction to be invalid, illegal, void or unenforceable in any respect, all other provisions of this Guaranty, or the application of such provision to Persons or circumstances other than those as to which it has been held invalid, illegal, void or unenforceable, shall nevertheless remain in full force and effect and will in no way be affected, impaired or invalidated thereby. Upon such determination that any provision, or the application of any such provision, is invalid, illegal, void or unenforceable, the parties shall negotiate in good faith to modify this Guaranty so as to effect the original intent of the parties as closely as possible to the fullest extent permitted by applicable Law in an acceptable manner to the end that the transactions contemplated hereby are fulfilled to the greatest extent possible.

 

 

8


 

5.8 Financing. Guarantor acknowledges that Beneficiary intends to obtain financing, and Guarantor agrees to cooperate with Beneficiary and the Lenders in connection with such financing, including, but not limited to, entering into a Consent and Agreement with the Lenders, in a form substantially similar to Exhibit F-5 to the Agreement.

5.9 Governing Law; Jurisdiction.

5.9.1 This Guaranty and all claims arising out of or relating to this Guaranty and the transactions contemplated hereby shall be governed by the laws of the State of New York, without regard to the conflicts of law principles that would result in the application of the laws of any other jurisdiction.

5.9.2 Each Party (a) irrevocably submits to the exclusive jurisdiction of any federal court or state court sitting in the Southern District of New York in any dispute, claim or controversy arising under or relating to this Guaranty, (b) agrees that all claims in such action may be decided in such court, (c) waives, to the fullest extent it may effectively do so, the defense of inconvenient forum and (d) consents to the service of process by mail in accordance with the notice provisions of this Guaranty.

5.9.3 Each Party waives all right to trial by jury in any action or proceeding to enforce or defend any rights under this Guaranty and any document executed in connection herewith.

[signature page follows]

 

 

9


 

IN WITNESS WHEREOF, this Guaranty has been duly executed and delivered by Guarantor as of the date first above written.

 

GUARANTOR
KBR, INC.
By:   /s/ Mark Sopp
Name:   Mark Sopp
Title:   Executive Vice President and Chief Financial Officer

 

BENEFICIARY
VENTURE GLOBAL PLAQUEMINES LNG, LLC
By:   /s/ Jonathan Thayer
Name:   Jonathan Thayer
Title:   Chief Financial Officer

[Contractor Guaranty Signature Page]

 

Exhibit 10.4

Execution Version

GUARANTY

This GUARANTY, dated as of April 21, 2021 (this “Guaranty”), is made by ZACHRY HOLDINGS, INC., a Delaware corporation (“Guarantor”), for the benefit of VENTURE GLOBAL Plaquemines LNG, LLC, a Delaware limited liability company (the “Beneficiary”). The Guarantor and Beneficiary are referred to herein individually as a “Party” and collectively as the “Parties”.

RECITALS

WHEREAS, the execution and delivery of this Guaranty is required pursuant to section 9.3 of that certain Amended and Restated Engineering, Procurement and Construction Agreement (as may be amended, modified or supplemented from time to time, the “Agreement”), dated as of the date hereof, by and between KZJV LLC, a Texas limited liability company (“Obligor”) and Beneficiary;

WHEREAS, this Guaranty is entered into by the Guarantor as an inducement for Beneficiary to enter into and consummate the transactions contemplated by the Agreement; and

WHEREAS, Guarantor will derive substantial benefit from the consummation of the transactions contemplated by the Agreement.

NOW, THEREFORE, in consideration of the mutual covenants contained herein and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Guarantor and Beneficiary agree as follows:

ARTICLE 1

DEFINITIONS AND CONSTRUCTION

1.1 Definitions. All capitalized terms used but not defined herein shall have the meanings set forth for such terms in the Agreement.

ARTICLE 2

GUARANTY

2.1 Guaranty. Guarantor hereby irrevocably, absolutely, fully and unconditionally guarantees to Beneficiary and its successors and assigns the timely and complete payment and performance when and as due (whether at the stated due date, by acceleration or otherwise) of all obligations of Obligor arising under the Agreement (the “Guaranteed Obligations”), subject to the limitations and rights of Obligor set forth in the Agreement.


 

2.2 No Release or Discharge. This Guaranty is a direct and primary obligation of Guarantor and shall be an irrevocable, unconditional, absolute and continuing guaranty, irrespective of the following potential defenses:

2.2.1 any invalidity, voidability or unenforceability of, or defect or deficiency applicable to Obligor in respect of, the Agreement or any other documents executed in connection with the Agreement based on Obligor’s lack of corporate power and authority to enter into the Agreement or such other documents or the failure of the Agreement or such other documents to be duly authorized and executed by Obligor and its signatories;

2.2.2 any postponement or extension of the date on which any payment must be made pursuant to the Agreement or postponement or extension of the date on which any act must be performed by Obligor thereunder, provided that any such postponement or extension shall be deemed to apply to the Guarantor’s obligations hereunder in the same way that it applies to Obligor’s obligations under the Agreement;

2.2.3 whether or not Guarantor received direct notice of or consented to any modification, amendment, supplement, renewal or waiver of the Agreement or any of the terms or conditions of the Agreement, including under a Change Order, provided that the Guaranteed Obligations shall not be greater than the obligations of Obligor under the Agreement, as the Agreement may be so modified, amended, supplemented, renewed or waived without Guarantor’s consent;

2.2.4 any failure, omission or delay on the part of Beneficiary or any other Person to confirm or comply with any of the terms or conditions of the Agreement or any other documents executed in connection with the Agreement;

2.2.5 except as to applicable statutes of limitation or other contractual period of limitation, the failure, omission, delay, or refusal by Beneficiary to exercise against Obligor, in whole or in part, any right or remedy held by Beneficiary with respect to the Agreement;

2.2.6 any legal disability of Guarantor, or any release or discharge of Guarantor by a bankruptcy court;

2.2.7 any stay applicable to any enforcement of the Guaranteed Obligations against Obligor;

2.2.8 any rights of subrogation, reimbursement, indemnity or contribution that Guarantor or Beneficiary may have against Obligor;

2.2.9 any lack of knowledge by Guarantor as to the condition (including financial) of Obligor, since Guarantor shall be responsible for obtaining its own knowledge of such condition;

2.2.10 any election of remedies by Beneficiary, even if such election of remedies impairs or destroys Guarantor’s right of subrogation against Obligor;

2.2.11 any merger, consolidation, termination of or change in corporate existence, structure or ownership of Obligor, any JV Member or Guarantor, or any insolvency, bankruptcy, reorganization or other similar proceeding affecting Obligor, and JV Member or its assets;

 

2


 

2.2.12 any amendment, termination or material breach of, or any dispute, claim, litigation or arbitration arising under, the JV Agreement; or

2.2.13 subject to the defenses available to Guarantor pursuant to Section 2.6.2, any other occurrence or circumstance which might otherwise constitute a legal or equitable discharge or defense of a guarantor or which might otherwise limit recourse against Guarantor all without notice to or further assent by Guarantor, who shall remain bound by this Guaranty, which shall remain in full force and effect until all of the Guaranteed Obligations have been paid in full or otherwise extinguished.

No action which Beneficiary shall take or fail to take in connection with the Guaranteed Obligations, nor any course of dealing with Obligor or any other person, shall release Guarantor’s obligations hereunder, affect this Guaranty in any way, or afford Guarantor any recourse against Beneficiary. This Guaranty is in no way conditioned or contingent upon any attempt to collect from or enforce performance or payment by Obligor or upon any other event, contingency or circumstance whatsoever. Beneficiary shall not be obligated to take any action, obtain any judgment or file any claim prior to enforcing this Guarantee. Beneficiary shall not be obligated to file any claim relating to the Obligations in the event that Obligor becomes subject to a bankruptcy, reorganization or similar proceeding, and the failure of Beneficiary to so file shall not affect Guarantor’s obligations hereunder.

This Guaranty shall continue to be effective or be reinstated, as the case may be, if at any time any payment of any of the Guaranteed Obligations are annulled, set aside, invalidated, declared to be fraudulent or preferential, rescinded or must otherwise be returned, refunded or repaid by Beneficiary upon the insolvency, bankruptcy, dissolution, liquidation or reorganization of Obligor or any other guarantor, or upon or as a result of the appointment of a receiver or conservator of, or trustee for Obligor or any other guarantor or any substantial part of its property or otherwise, all as though such payment or payments had not been made.

2.3 Waiver of Rights. Subject to the limitations expressly set forth in this Guaranty, Guarantor understands and agrees that the guaranty contained in Section 2.1 shall be a continuing guaranty. Guarantor hereby expressly waives:

2.3.1 notice of acceptance of this Guaranty, of the creation or existence of any of the Guaranteed Obligations, of any of the matters described in Section 2.2 and of any action by Beneficiary in reliance hereon or in connection herewith;

2.3.2 notice of the entry into the Agreement between Obligor and Beneficiary and of any amendments, supplements or modifications thereto; or any waiver of consent under the Agreement, including waivers of the payment and performance of the obligations thereunder;

 

3


 

2.3.3 notice of any increase, reduction or rearrangement of Obligor’s obligations under the Agreement or any extension of time for the payment of any sums due and payable to Beneficiary under the Agreement;

2.3.4 presentment, demand for payment, notice of acceptance, notice of dishonor or nonpayment, protest and notice of protest or any other notice with respect to the Guaranteed Obligations; and

2.3.5 any requirement that suit be brought against, or any other remedy or action by Beneficiary be taken against, or any notice of default or other notice be given to, or any demand be made on Obligor or any other person, or that any other action be taken or not taken as a condition to Guarantor’s liability for the Guaranteed Obligations under this Guaranty or as a condition to the enforcement of this Guaranty against Guarantor.

2.4 No Subrogation. Guarantor will not exercise and irrevocably agrees to waive any rights against Obligor which it may acquire by way of subrogation, reimbursement, exoneration, contribution or indemnification in connection with this Guarantee by any payment made hereunder or otherwise, until all Guaranteed Obligations shall have been fully and indefeasibly paid and performed. If (a) Guarantor makes payment to Beneficiary of all or any part of the Guaranteed Obligations and (b) all of the then outstanding Guaranteed Obligations shall have been paid in full, Beneficiary shall, at Guarantor’s request, execute and deliver to Guarantor documents to evidence the transfer by subrogation to Guarantor of any interest in the Guaranteed Obligations resulting from such payment by Guarantor. If any amount shall be paid to Guarantor on account of such subrogation, contribution, reimbursement or indemnity rights at any time when all of the Guaranteed Obligations and all amounts owing hereunder shall not have been performed and paid in full, such amount shall be held by Guarantor in trust for Beneficiary, segregated from other funds of Guarantor, and shall, forthwith upon receipt by Guarantor, be turned over to Beneficiary in the exact form received by Guarantor (duly endorsed by Guarantor to Beneficiary, if required), to be applied against the Guaranteed Obligations, whether or not matured, in such order as Beneficiary may determine.

2.5 Demand and Payment. Beneficiary may provide written notice to Guarantor pursuant to Section 5.1 at any time if Obligor fails to punctually pay or perform any of the Guaranteed Obligations. There are no other requirements of notice, presentment or demand. Guarantor shall pay, or cause to be paid, such Guaranteed Obligations within five (5) Business Days of receipt of such notice, unless, within such period, the default giving rise to such notice has been remedied. If Beneficiary is prevented from making a demand on Guarantor as a result of any applicable Law, any injunction, order or other action of any court or other Government Authority or any stay, moratorium or other action in any bankruptcy, insolvency or other similar proceeding, Guarantor shall not be excused from paying and performing its obligations under this Guaranty as and when due. All payments by Guarantor hereunder shall be paid without setoff or deduction in U.S. dollars in immediately available funds to such accounts as may be designated by Beneficiary from time to time. Guarantor agrees to pay on demand all fees and out of pocket expenses (including the reasonable fees and expenses of Beneficiary’s counsel) in any way relating to the enforcement or protection of the rights of Beneficiary hereunder. Any amount due and payable hereunder shall, if not paid when due, accrue interest at the Late Payment Rate from the date such payment was due until the date such payment is made in full.

 

4


 

2.6 Primary Liability of Guarantor; Guarantor’s Defenses.

2.6.1 Guarantor agrees that Beneficiary may enforce this Guaranty without the necessity at any time of resorting to or exhausting any other security or collateral, including any other Contractor Guarantee provided by any other Contractor Guarantor, or exercising or exhausting any other remedies against Obligor or any other Contractor Guarantor. This is a guaranty of payment and performance when and as due and not merely of collection.

2.6.2 Notwithstanding anything to the contrary stated herein or in the Agreement or any documents related thereto, Guarantor’s undertakings and obligations hereunder with respect to the Agreement are derivative of and not in excess of Obligor’s obligations under the Agreement and Guarantor may assert as a defense, right of set-off or counterclaim to its obligations hereunder any defense, right of set-off or counterclaim that Obligor may have to such Guaranteed Obligations under the Agreement or otherwise, even if Obligor fails to raise the same, except (i) a defense based on the discharge of the Guaranteed Obligations as to Obligor in a bankruptcy or insolvency proceeding or (ii) other defenses expressly waived hereunder.

2.7 Continuing Guaranty. Guarantor’s obligations under Section 2.1 of this Guaranty shall continue in force and effect until the Guaranteed Obligations have been fully performed or otherwise extinguished under the Agreement, at which time this Guaranty and all of Guarantor’s obligations hereunder shall terminate and expire. Guarantor agrees that any judgment between Obligor and Beneficiary under the Agreement (whether in contested litigation or arbitration or otherwise) shall be conclusive and binding on Guarantor for the purposes of determining Guarantor’s obligations under this Guaranty.

ARTICLE 3

REPRESENTATIONS AND WARRANTIES

3.1 Representations and Warranties of Guarantor. Guarantor represents and warrants as follows:

3. 1.1 It is a corporation, duly formed, validly existing and in good standing under the laws of the State of Delaware.

3.1.2 It has all requisite power and authority to execute and deliver this Guaranty and to perform all obligations to be performed by it hereunder. The execution and delivery of this Guaranty and the consummation of the transactions contemplated hereby have been duly and validly authorized and approved by all requisite corporate action on its part. This Guaranty has been duly and validly executed and delivered by it and this Guaranty constitutes a valid and binding obligation of it, enforceable against it in accordance with its terms.

 

5


 

3.1.3 The execution and delivery of this Guaranty by it and the performance of its obligations hereunder by it do not and shall not: (i) violate any applicable Law or require any filing with, consent, approval or authorization of, or notice to, any Government Authority or any other Person, except as otherwise obtained prior to the date hereof, (ii) violate any of its organizational documents or (iii) breach or conflict with any material contract to which it is a party or by which it may be bound, result in the termination of any such material contract, result in the creation of any lien upon any of its assets or constitute an event which, after notice or lapse of time or both, would result in any such breach, termination or creation of a lien upon any of its assets.

ARTICLE 4

COVENANTS

4.1 Guarantor Financial Statements. As soon as available, but in any event within sixty (60) Days after the end of the first three fiscal quarters of the Guarantor, Guarantor shall make available to Obligor for delivery to Beneficiary the unaudited and consolidated balance sheet of the Guarantor, as of the end of such quarter, the related consolidated statements of income, cash flows, and retained earnings and stockholders’ equity for such quarter, all of which shall be certified by the chief financial officer or equivalent officer of the Guarantor subject to normal year -end audit adjustments. As soon as available, but in any event no later than one-hundred twenty (120) Days after the end of each fiscal year of the Guarantor, Guarantor shall deliver to Beneficiary a copy of the audited consolidated balance sheets at the end of each such year as well as the related consolidated statements of income, retained earnings, and cash flows for such year.

4.2 Joint Venture. Guarantor shall not, and shall cause the JV Member with whom it is Affiliated not to, in each case without the prior written consent of Beneficiary:

4.2.1 amend or modify the JV Agreement in a manner that would cause the representation of Obligor set forth in section 28.2.9 of the Agreement, if repeated as of such time, to be materially inaccurate or misleading in any respect;

4.2.2 assign, sell, transfer, encumber (other than under the JV Agreement) or convey its ownership interests in Obligor to any Person other than its wholly-owned Affiliate or the other JV Member in accordance with the JV Agreement;

4.2.3 amend or modify the division of responsibilities between the JV Members in the JV Agreement in a manner that would be materially inconsistent with the division of responsibilities set forth in exhibit A to the Agreement;

4.2.4 amend, modify or waive any of its “step-in” rights under the JV Agreement; or

4.2.5 permit Obligor to engage in any business other than the performance of the Agreement and such other activities as are incidental thereto.

 

6


 

4.3 Maintenance of Existence. Guarantor shall, and shall cause the JV Member with whom it is Affiliated to, cause Obligor to preserve, renew and keep in full force and effect its organizational existence and good standing in its jurisdiction of formation and maintain and renew all of the powers, licenses, rights, privileges and franchises necessary for its performance of the Agreement and in the normal conduct of its business. Guarantor shall not, and shall cause JV Member with whom it is Affiliated not to, seek or voluntarily consummate any liquidation, bankruptcy, dissolution or reorganization of Obligor.

4.4 Notice of Disputes. Guarantor shall provide prompt written notice to Beneficiary of any material dispute, claim, litigation, arbitration or other proceeding arising under the JV Agreement.

4.5 No Restriction. Neither Guarantor nor any of its Affiliates shall agree or become subject to any restriction, contractual or otherwise, that would prohibit it or any of its Affiliates from bidding for or entering into a contract or guarantee, as applicable, in respect of the second ten (10) MTPA (nameplate) phase of the Plaquemines LNG export project under development by Beneficiary and its Affiliates, unless Beneficiary’s prior written approval of such restriction is obtained.

ARTICLE 5

MISCELLANEOUS

5.1 Notices. All notices and other communications required or permitted to be given by any provision of this Guaranty shall be in writing and mailed (certified or registered mail, postage prepaid, return receipt requested) or sent by hand or overnight courier, or by facsimile transmission (with acknowledgment received), charges prepaid and addressed to the intended recipient as follows, or to such other addresses or numbers as may be specified by a Party from time to time by like notice to the other parties:

If to Guarantor, at:

If to Beneficiary, at:

All notices and other communications given in accordance with the provisions of this Guaranty shall be deemed to have been given and received: (i) when delivered, if delivered by hand or transmitted by facsimile (with acknowledgment received); (ii) five (5) Business Days after the same are sent by certified or registered mail, postage prepaid, return receipt requested; or (iii) one (I) Business Day after the same are sent by a reliable overnight courier service, with acknowledgment of receipt.

 

7


 

5.2 Assignment. This Guaranty shall be binding upon and inure to the benefit of the Parties and their respective successors and permitted assigns. Neither Party may assign (by contract, stock sale, operation of law or otherwise) either this Guaranty or any of its rights, interests, or obligations hereunder without the express prior written consent of the other Party, and any attempted assignment, without such consent, shall be null and void; provided, however that Beneficiary may assign this Agreement, without the consent of Guarantor (but with written notice to Guarantor) in connection with (i) an assignment of the Agreement by Beneficiary permitted under the Agreement or (ii) a collateral assignment of this Guaranty by Beneficiary to any Lender.

5.3 Rights of Third Parties. Nothing expressed or implied in this Guaranty is intended or shall be construed to confer upon or give any Person, other than Beneficiary, any right or remedies under or by reason of this Guaranty.

5.4 Entire Agreement. This Guaranty constitutes the entire agreement between the Parties with respect to the subject matter hereof and supersedes any prior understandings, negotiations, agreements, or representations between the Patties of any nature, whether written or oral, to the extent they relate in any way to the subject matter hereof.

5.5 Counterparts. This Guaranty may be executed in any number of counterparts, each of which shall be deemed an original but all of which together will constitute one and the same instrument.

5.6 Amendments. This Guaranty may be amended or modified in whole or in part, and terms and conditions may be waived, only by a duly authorized agreement executed by Guarantor and Beneficiary which makes reference to this Guaranty.

5.7 Severability. If any provision of this Guaranty or the application of any such provision to any Person or circumstance shall be declared by any court of competent jurisdiction to be invalid, illegal, void or unenforceable in any respect, all other provisions of this Guaranty, or the application of such provision to Persons or circumstances other than those as to which it has been held invalid, illegal, void or unenforceable, shall nevertheless remain in full force and effect and will in no way be affected, impaired or invalidated thereby. Upon such determination that any provision, or the application of any such provision, is invalid, illegal, void or unenforceable, the parties shall negotiate in good faith to modify this Guaranty so as to effect the original intent of the parties as closely as possible to the fullest extent permitted by applicable Law in an acceptable manner to the end that the transactions contemplated hereby are fulfilled to the greatest extent possible.

5.8 Financing. Guarantor acknowledges that Beneficiary intends to obtain financing, and Guarantor agrees to cooperate with Beneficiary and the Lenders in connection with such financing, including, but not limited to, entering into a Consent and Agreement with the Lenders, in a form substantially similar to Exhibit F-5 to the Agreement.

 

8


 

5.9 Governing Law; Jurisdiction.

5.9.1 This Guaranty and all claims arising out of or relating to this Guaranty and the transactions contemplated hereby shall be governed by the laws of the State of New York, without regard to the conflicts of law principles that would result in the application of the laws of any other jurisdiction.

5.9.2 Each Party (a) irrevocably submits to the exclusive jurisdiction of any federal court or state court sitting in the Southern District of New York in any dispute, claim or controversy arising under or relating to this Guaranty, (b) agrees that all claims in such action may be decided in such court, (c) waives, to the fullest extent it may effectively do so, the defense of inconvenient forum and (d) consents to the service of process by mail in accordance with the notice provisions of this Guaranty.

5.9.3 Each Party waives all right to trial by jury in any action or proceeding to enforce or defend any rights under this Guaranty and any document executed in connection herewith.

[signature page follows]

 

9


 

IN WITNESS WHEREOF, this Guaranty has been duly executed and delivered by Guarantor as of the date first above written.

 

GUARANTOR

ZACHRY HOLDINGS, INC.
By:   /s/ C. Ryan Frames
Name:   C. Ryan Frames
Title:   Senior Vice President, Finance & Treasury

 

BENEFICIARY

VENTURE GLOBAL PLAQUEMINES LNG, LLC

By:   /s/ Jonathan Thayer
Name:   Jonathan Thayer
Title:   Chief Financial Officer

 

 

10

Exhibit 10.5

Execution Version

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

LIMITED NOTICE TO PROCEED NO. 1 (ITP)

September 24, 2021

 

1.

Pursuant to Section 4.2 of the Amended and Restated Engineering, Procurement and Construction Agreement, dated as of April 21, 2021 (the “Agreement”), by and between Venture Global Plaquemines LNG, LLC (“Owner”), a limited liability company duly organized and validly existing under the laws of the State of Delaware, and KZJV LLC, a limited liability company duly organized and validly existing under the laws of the State of Texas (the “Contractor”), this notice shall serve as the Limited Notice to Proceed No. 1 (this “LNTP (ITP)”) from Owner to Contractor authorizing Contractor to enter into a Subcontract with ITP SA (the “ITP Subcontract”) and proceed with the LNTP Work described in the attached Exhibit 1 (the “LNTP Work (ITP)”) and authorized by this LNTP (ITP) pursuant to the terms and conditions of the Agreement. This LNTP (ITP) shall be subject to, and the LNTP Work (ITP) shall be performed in accordance with, the terms and conditions of the Agreement; provided, that Contractor shall not be responsible for the performance of any obligations under the Agreement that arise solely as the result of issuance of a Limited Notice to Proceed, except as expressly provided for herein.

 

2.

The LNTP (ITP) Work is additional scope not yet incorporated in the Work, Target Price and Project Schedule, and the Parties agree to cooperate in good faith in accordance with Article 12 of the Agreement to affect such incorporation, following the performance of the LNTP Work (ITP). The goal of the LNTP Work (ITP) is to protect the Project Schedule under the Agreement by allowing Contractor to commence the LNTP Work (ITP) prior to the Notice to Proceed under the Agreement. All work performed under this LNTP (ITP) shall be considered “Work” under the Agreement.

 

3.

Pursuant to Section 41.3 of the Agreement, Owner and Contractor acknowledge and agree that, for the purposes of this LNTP (ITP) only, Owner shall have no obligation to:

 

  (a)

furnish nonexclusive access to the Job Site to Contractor pursuant to Section 3.7.1 of the Agreement, unless approved in writing by Owner;

 

  (b)

provide legal rights for ingress to and egress from the Job Site for Contractor and its Subcontractors for the performance of the Work pursuant to Section 3.7.2 of the Agreement, unless approved in writing by Owner; and

 

  (c)

fumish personnel for training, testing, operation and maintenance of the Project pursuant to Section 3.7.4.

 

4.

Owner and Contractor acknowledge and agree that Owner shall have no obligation under Section 26.3 of the Agreement to obtain and maintain any insurance during the period of performance of the LNTP (ITP) Work.

 

5.

Pursuant to Section 3.7.3 of the Agreement and solely for the purposes of the prosecution of the LNTP Work (ITP) under this LNTP (ITP), Owner hereby designates [***] as the Owner’s Representative. Pursuant to Section 3.8.32 of the Agreement and solely for the purposes of the prosecution of the LNTP Work (ITP) under this LNTP (ITP), Contractor hereby designates [***] as the Contractor’s Representative.


 

6.

Notwithstanding anything contained in Section 6.3 of the Agreement to the contrary, Owner and Contractor agree that Reimbursable Costs incurred in the performance of the LNTP Work (ITP), together with Contractor’s G&A, shall be invoiced to Owner during the month following the month during which such LNTP Work (ITP) is performed. Amounts invoiced to Owner shall be paid (excluding Contractor’s Margin) within thirty (30) days of receipt of the relevant invoice. Upon issuance of Notice to Proceed, Contractor’s Margin associated with this LNTP Work (ITP) shall be included and paid in the initial Margin Milestone. If Notice to Proceed is not issued by Owner, then such Contractor’s Margin shall be included in the final invoice issued hereunder and paid upon termination of this LNTP (ITP). Owner shall pay Contractor a fixed amount of [***], due and payable upon the issuance of this LNTP (ITP), solely for Contractor to make payments to ITP SA due and owing under the ITP Subcontract in accordance with the terms thereof.

 

7.

Owner and Contractor acknowledge and agree that the amount payable to Contractor under this LNTP (ITP) shall not exceed the amount due to ITP SA under the ITP Subcontract through [***] or [***]. For the avoidance of doubt, Contractor shall not place orders for, commence the fabrication of or otherwise incur any liability or costs relating to procurement of Materials in connection with the LNTP Work (ITP) under this LNTP (ITP) without Owner’s pri or written consent.

 

8.

Upon commencing LNTP Work (ITP), but not later than ten (10) Business Days following the date of this notice, Contractor shall establish a coordination procedure with Owner to align key participants and establish protocols for execution of the LNTP Work (ITP).

 

9.

Except as expressly set forth in this LNTP (ITP), nothing in this LNTP (ITP) shall be construed to amend or modify the Agreement in any respect. Unless otherwise defined herein, capitalized terms used herein shall have the meanings ascribed to them in the Agreement.

[SIGNATURES ON THE NEXT PAGE]

 

2


 

IN WITNESS WHEREOF, the Parties hereto have caused this LNTP (ITP) to be executed as of the day and year first above written.

 

OWNER:

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC

By:   /s/ Keith Larson
Name:   Keith Larson
Title:   General Counsel

CONTRACTOR:

KZJV LLC
By:   /s/ Pamela Roche
Name:   Pamela Roche
Title:   Project Director
By:   /s/ Thomas Augustine
Name:   Thomas Augustine
Title:   Deputy Project Director

 

3


 

EXHIBIT 1

LNTP WORK (ITP)

[Omitted]

 

4


 

ANNEX A

EXHIBIT J TO THE ITP SUBCONTRACT

Form of Limited Notice to Proceed

[Omitted]

 

5


 

ATTACHMENT 1

ITP LNTP WORK

[Omitted]

 

6

Exhibit 10.6

(Execution Version)

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER NO.1

 

Date: May 17, 2022

     

Change Order No. 1

     

Reference: Batture Clearing, Levee

     

Bridge Crane Pad and Mammoet

     

Bridge Work Pad

     

Documents:

     

Change Order Requests as per letter

     

PQ-PRM-KZV-VGL-LET-00026,

     

PQ-PRM-KZV-VGL-LET-00065-

     

22, No. CP-25 Rev.1 related to

     

Change Proposal Release #13, and

     

as per letter PQ-PRM-KZV-VGL-

     

LET-00031 CP-33 and CP-34

     

related to Change Proposal Release

     

#4.

Venture Global Plaquemines LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware (“Owner”), and KZJV LLC, a limited liability company duly organized and validly existing under the laws of the State of Texas (the “Contractor”), hereby agree to the following change to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January 7, 2022, by and between Owner and Contractor (as amended, supplemented or otherwise modified, the “Agreement”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, agreed upon by the Parties pursuant to Article 12 of the Agreement, is considered an amendment to the Agreement. Except to the extent specifically described in this Change Order, the change(s) set forth herein do(es) not relieve Contractor of its responsibilities set forth in the Agreement.

Provided that this Change Order is executed by both Parties, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Contractor fully for such effects, unless otherwise provided in the detailed description below.

Scope: The following items shall be included in the Agreement as Reimbursable Work:

Batture Clearing:

 

  (a)

In accordance with Section 2 of LNTP No. 2, dated as of November 29, 2021, issued under the Agreement, Contractor shall perform batture clearing, including clearing and removal of trees, underbrush, grass, vegetation, trash, and debris on the Mississippi River


 

(Execution Version)

Levee Batture to within six inches of the existing ground, between the toe of the levee and the edge of the river water line, as described further in the Subcontract with Brown Industrial Construction LLC authorized pursuant to such LNTP No. 2.

Levee Bridge Crane Pad:

 

  (b)

Section 3.9 of Exhibit A to the Agreement is hereby amended by inserting a new Clause (4) immediately following Clause (3):

“4) Contractor shall provide the detailed design and perform all necessary soil improvements to provide support for the module M113 crane pad location following the recommendations included in the Fugro Bearing Capacity and Slope Stability Study dated October 15, 2021, attached hereto in Attachment 7. The soil improvement plan and sections are depicted in drawing number PQ-000000-CIV-SIP-KBR-00106-001 Rev 5A (Figure 1) and the details of the soil improvement sections near the levee as depicted in Fugro Bearing Capacity and Slope Stability Study in Attachment 7:

[***]

 

  (c)

Exhibit A to the Agreement is hereby amended by inserting Appendix 1 of this Change Order hereto as “Attachment 7” immediately following Attachment 6 thereof.

 

  (d)

Mammoet Bridge Work Pad:

Section 3.9 of Exhibit A to the Agreement is hereby amended by inserting a new Clause (5) immediately following Clause (4):


 

(Execution Version)

“5) Contractor shall perform site preparation work, including supply and installation of a minimum of twelve-inch crushed rock, geogrid, and geotextile for the area south of the Mississippi River Levee Heavy Haul bridge piling workspace, and as more particularly described in the Area North of Highway 23 and East of Plant Entrance Soil Improvement Plan of drawing PQ-000000-CIV-SIP-KZV-00109-001 Rev A, and more specifically, the area depicted in the red box below:

[***]

The Change Proposals referenced herein shall be deemed to supplement the above scopes of Work to the extent of technical, engineering or construction related items contained therein that support the execution of the Work authorized herein. As to the Target Price or Project Schedule, the Change Proposals shall not otherwise supersede, modify or amend any terms or conditions of this Change Order or the Agreement nor entitle Contractor to any further changes to this Change Order.

Price:

 

Initial Target Price:

   [***]   

Estimated Value of Change Order:

   [***], itemized as follows:
    

Section1

  

Amount of

Reimbursable

Costs ($)

  

Section (a) (CP-25 Rev1)

   [***]
  

Section (b) (CP-33)

   [***]
  

Section (d) (CP-34)

   [***]
   Total                [***]

Adjusted Target Price as a result

   [***]   

 

 

1 

“Section” refers to the sections above in this Change Order under “Scope”.


 

(Execution Version)

of this Change Order (if applicable):

Deliverable Schedule:

This Change Order shall have no impact on the Project Schedule or Applicable Deadlines.

This Change Order is not valid, except as otherwise provided in the Agreement, until fully executed by Contractor and Owner.

[Signatures on the following page.]


 

(Execution Version)

IN WITNESS WHEREOF, the Parties have caused this Change Order to be executed by their duly authorized representatives as of the date and year first above written.

 

Venture Global Plaquemines LNG, LLC

   

KZJV LLC

By:  

/s/ Keith Larson

    By:  

/s/ Pamela C. Roche

Name:   Keith Larson     Name:   Pamela C. Roche
Title:   Secretary     Title:   VP Project Management

 

   

KZJV LLC

          By:  

/s/ Thomas Augustine

      Name:   Thomas Augustine
      Title:   Deputy Project Director


 

(Execution Version)

APPENDIX 1

Attachment 7

Fugro Bearing Capacity and Slope Stability Study

[Omitted]

Exhibit 10.7

(Execution Version)

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER NO. 2

 

Date May 20, 2022

     

Change Order No. 2

     

Reference: Exhibit W (Open Cost Items)

Venture Global Plaquemines LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware (“Owner”), and KZJV LLC, a limited liability company duly organized and validly existing under the laws of the State of Texas (“Contractor”), hereby agree to the following change to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January 7, 2022, by and between Owner and Contractor (as amended, supplemented or otherwise modified, the “Agreement”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, agreed upon by the Parties pursuant to Article 12 of the Agreement, is considered an amendment to the Agreement. Except to the extent specifically described in this Change Order, the change(s) set forth herein do(es) not relieve Contractor of its responsibilities set forth in the Agreement.

Provided that this Change Order is executed by both Parties, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Contractor fully for such effects, unless otherwise provided in the detailed description below.

Scope:

The following provisions of the Contract are deleted in their entirety and the word “[Reserved]” is inserted in their place: (1) the definition of “Open Cost Item” in Article 1; (2) Section 6.1.3; and (3) Exhibit W.

Price:

The Parties have agreed to reduce the Target Price by the amount of [***] and, subject to the terms of this Change Order, a further additional reduction in an amount up to [***] in respect of the following items:

 

No.

  

Open Cost Item

  

Increase (Decrease) to

Target Price in this

Change Order

  

Potential Additional Reductions
in Target Price

1   

Spare flare KO drum needed for continuous operation of facility

      A minimum of [***] and a maximum of [***]

2

  

Feeders for utility substations

   [***]    N/A


 

(Execution Version)

 

3   

Essential feeders moved to underground

   [***]    N/A
4   

Routing of redundant power and control cables

      A minimum of [***] and a maximum of [***]
5   

Physical separation of cables to critical motors

      A minimum of [***] and a maximum of [***]
6   

Change in BOG compressor motor type

   [***]    N/A
7   

Added BTU analyzer

   [***]    N/A
8   

Instrument air receiver sizing change

      A minimum of [***] and a maximum of [***]
9   

BOG compressor supply pressure to GTG

   [***]    N/A
10   

Common steam condensate storage for STGs

   [***]    N/A
11   

BOG Compressor Control Building

   [***]    N/A
12   

Additional heavy haul roads

   [***]    N/A
13   

Phase 2 Minimal Soils Improvements to support PH1

   [***]    N/A
14   

Temporary facility – water storage

   [***]    N/A
15   

New loading isolation valves

   [***]    N/A
16   

Increased FP due to larger LNG jetty sump

   [***]    N/A
17   

Redundant Transmitters in Power Island

      A minimum of [***] and a maximum of [***]
18   

Essential power to LTS Blocks 6-9, PTS, and Flare areas

   [***]    N/A
19   

ACC Initial vacuum (Hogging) change

   [***]    N/A
20   

Increase IP steam temp for gland steam seal

   [***]    N/A
21   

Start up Fuel gas Heater

   [***]    N/A
22   

Demin water pump

   [***]    N/A
23   

Fresh water pump

   [***]    N/A
24   

Air Compressor capacity change

      A minimum of [***] and a maximum of [***]


 

(Execution Version)

 

25   

Startup Air Compressor capacity change

   [***]    N/A
26   

LTS Yard OFE Support

   [***]    N/A
27   

PTS Yard OFE Support

   [***]    N/A
28   

BH Vendor Support

   [***]    N/A
29   

Additional Modules

   [***]    N/A
30   

One line changes

   [***]    N/A
31   

Flare height

      A minimum of [***] and a maximum of [***]
32   

Home Office Hour Increase

      A minimum of [***] and a maximum of [***]
33   

Additional gates in SSW

   [***]    N/A
Subtotals    [***]    A minimum reduction of [***] and a maximum
reduction of [***] (the “Maximum Additional
Reduction
”)

Less the Maximum Additional Reduction

   [***]    N/A

Total Value of this Change Order

   [***]    N/A

Owner and Contractor agree to, within ninety (90) days of the date of this Change Order, evaluate and agree upon the amount of each item identified in Nos. 1, 4, 5, 8, 17, 24, 31 and 32 above, such amount to be not less than the minimum and not more than the maximum values set forth in the column relating to such item. The aggregate agreed-upon net reduction to the Target Price resulting therefrom shall be documented in a subsequent Change Order.

 

Initial Target Price:

  

[***]

Current Target Price:

   [***]

Value of Change Order:

   [***]

Adjusted Target Price as a result of this Change Order:

   [***]

Deliverable Schedule:

This Change Order shall have no impact on the Project Schedule or Applicable Deadlines.


 

(Execution Version)

This Change Order is not valid, except as otherwise provided in the Agreement, until fully executed by Contractor and Owner.

[Signatures on the following page.]


 

(Execution Version)

IN WITNESS WHEREOF, the Parties have caused this Change Order to be executed by their duly authorized representatives as of the date and year first above written.

 

Venture Global Plaquemines LNG, LLC

   

KZJV LLC

By:  

/s/ Keith Larson

    By:  

/s/ Pamela C. Roche

Name:   Keith Larson     Name:   Pamela C. Roche
Title:   Secretary     Title:   VP Project Management
   

KZJV LLC

      By:  

/s/ Thomas Augustine

      Name:   Thomas Augustine
      Title:  

Deputy Project Director

Exhibit 10.8

(Execution Version)

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER NO. 3

 

Date: September 30, 2022    Change Order No. 3
   Reference: Exhibit W (Open Cost Items)

Venture Global Plaquemines LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware ( “Owner”), and KZJV LLC, a limited liability company duly organized and validly existing under the laws of the State of Texas ( “Contractor” ), hereby agree to the following change to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January 7, 2022, by and between Owner and Contractor (as amended, supplemented or otherwise modified, the “Agreement ). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, agreed upon by the Parties pursuant to Article 12 of the Agreement, is considered an amendment to the Agreement. Except to the extent specifically described in this Change Order, the change(s) set forth herein do(es) not relieve Contractor of its responsibilities set forth in the Agreement.

Provided that this Change Order is executed by both Parties, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Contractor fully for such effects, unless otherwise provided in the detailed description below.

Price:

Further to Change Order No. 2, dated May 20, 2022 (“Change Order No. 2”), the Parties have agreed to an additional reduction to the Target Price in an amount equal to [***] in respect of the following items identified in Change Order No. 2:

 

No.

  

Open Cost Item

   Additional Reductions to
Target Price
 
1    Spare flare KO drum needed for continuous operation of facility      [ ***] 
4    Routing of redundant power and control cables      [ ***] 
5    Physical separation of cables to critical motors      [ ***] 
8    Instrument air receiver sizing change      [ ***] 
17    Redundant Transmitters in Power Island      [ ***] 
24    Air Compressor capacity change      [ ***] 
31    Flare height      [ ***] 
32    Home Office Hour Increase      [ ***] 
   Total Value of this Change Order No.3      [ ***] 


(Execution Version)

 

Initial Target Price:    [***]
Current Target Price:    [***]
Value of Change Order:    [***]
Adjusted Target Price as a result of this Change Order:   

[***]

Deliverable Schedule:

This Change Order shall have no impact on the Project Schedule or Applicable Deadlines.

This Change Order is not valid, except as otherwise provided in the Agreement, until fully executed by Contractor and Owner.

[Signatures on the following page.]


(Execution Version)

IN WITNESS WHEREOF, the Parties have caused this Change Order to be executed by their duly authorized representatives as of the date and year first above written.

 

Venture Global Plaquemines LNG, LLC     KZJV LLC
By:  

/s/ Keith Larson

    By:  

/s/ Pamela C. Roche

Name:   Keith Larson     Name:   Pamela C. Roche
Title:   Secretary     Title:   VP Project Management
      KZJV LLC
      By:  

/s/ Thomas Augustine

      Name:   Thomas Augustine
      Title:   Deputy Project Director

Exhibit 10.9

Execution Version

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

AMENDMENT NO. 1 TO

SECOND AMENDED AND RESTATED

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

THIS AMENDMENT NO. 1 TO SECOND AMENDED AND RESTATED ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Amendment”), dated as of October 11, 2022, is entered into by and between VENTURE GLOBAL PLAQUEMINES LNG, LLC, a Delaware limited liability company (“Owner”), and KZN LLC, a Texas limited liability company (“Contractor”).

W I T N E S S E T H

WHEREAS, Owner and Contractor are parties to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement dated as of January 7, 2022 (the “Agreement”); and

WHEREAS, pursuant to Section 41.8 of the Agreement, the Parties desire to amend the Agreement effective as of July 31, 2022 (the “Amendment Effective Date”) as set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants and provisions herein contained, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby covenant and agree as follows:

1. Defined Terms. Capitalized terms not defined in this Amendment shall have the meaning given to such terms in the Agreement.

2. Amendments. Effective as of the Amendment Effective Date, the Agreement is hereby amended as follows:

(i) Article 1 of the Agreement is hereby amended to insert the following new defined terms in alphabetical order:

““Amendment Effective Date” means July 31, 2022.

“Base Target Price” means, as of any date, an amount equal to the sum of the Direct Costs and Agent for Contracts Costs components of the Target Price as of such date.

“Certificate of Achievement” means the certificate, in substantially the form set forth as Exhibit F-17, to be provided by Contractor confirming in writing that the particular Margin Milestone has been achieved and explaining how it was achieved.

 

1


“Contractor’s Margin” means Contractor’s profit margin for the Work which, in respect of each Margin Milestone shall be calculated as follows:

CM = Base Target Price x MP x FP

Where:

CM = Contractor’s Margin for the relevant Margin Milestone

MP = the Margin Percentage, as adjusted pursuant to Section 8.2.

FP = the fixed milestone percentage for the relevant Margin Milestone set forth in Appendix 1 of Exhibit D.

“Margin Milestones” means the events to be achieved by Contractor for payment of Contractor’s Margin as defined in Exhibit A and included as Appendix 1 of Exhibit D.”

(ii) Section 6.3.1 of the Agreement is hereby deleted in its entirety and the following shall be inserted in its place:

“6.3.1 Not later than the 15th day of each Month N, Contractor shall submit to Owner for its approval a Request for Payment (simultaneously sending copies to the Independent Engineer, as Owner may direct), which shall set forth: (a) a reasonable good faith estimate of (i) the Reimbursable Work activities that will be performed during the second month (“Month N+2”) immediately following such Month N and (ii) the Direct Costs and Contractor’s G&A associated with such Reimbursable Work activities (the sum of clauses (i) and (ii) being referred to herein as an “Estimated Monthly Amount”) less, in the case of the Initial Request for Payment, the amount of the advance payment described in Section 4.1.1; (b) except for the Initial Request for Payment, the amount owed to Contractor in respect of the Reimbursable Work performed during the preceding month(s), together with Contractor’s G&A and Contractor’s Margin associated with such Reimbursable Work, that has not been paid to Contractor during such preceding month(s), as applicable; (c) except for the Initial Request for Payment, the amount by which the aggregate amount of Estimated Monthly Amounts paid to Contractor during the preceding month(s) exceeds the actual Direct Costs incurred by Contractor in the performance of the Reimbursable Work during the preceding month(s), calculated as of the last day of the month immediately preceding such month, and the Contractor’s G&A associated with such Direct Costs payable by Owner in respect of such Reimbursable Work; (d) without duplication of amounts described in clauses (a) through (c) above, any other amounts that may be due and owing from Owner to Contractor or from Contractor to Owner pursuant to any other provision of this Agreement, as well as Contractor’s Margin for any and all Margin Milestones achieved by Contractor during or prior to Month N as per the schedule defined in Appendix 1 of Exhibit D; and (e) all information and documentation required by Section 6.3.3.”

 

2


(iii) Section 6.3.8 of the Agreement is hereby amended inserting the following new sentence immediately following the first sentence thereof:

“For the avoidance of doubt, no Contractor’s Margin in respect of any Margin Milestone shall be due and payable by Owner until such Margin Milestone has been achieved by Contractor, such achievement being confirmed by a Certificate of Achievement to be provided by Contractor together with the relevant Request for Payment.”

(iv) Section 6.3 of the Agreement is hereby amended by adding the following new Section 6.3.11 immediately following the end of Section 6.3.10:

“6.3.11 For each Margin Milestone that was achieved prior to the Amendment Effective Date, Owner or Contractor, as applicable, shall promptly (and in any event no later than November 30, 2022) pay or credit to the other Party any difference between the actual payment of Contractor’s Margin made in respect of such Margin Milestone and the amount calculated pursuant to the definition of “Contractor’s Margin”.

(v) Section 6.3 of the Agreement is hereby amended by adding the following new Section 6.3.12 immediately following the end of Section 6.3.11:

“6.3.12 The Parties acknowledge that the amount of Contractor’s Margin payable by Owner in respect of each Margin Milestone is calculated based on a percentage of the then applicable Base Target Price. The following methodology will be applied with respect to any (i) adjustment to the Base Target Price after the Effective Date, (ii) instance where the aggregate amount of Direct Costs and Agent for Contract Costs incurred in the performance of the Reimbursable Work exceeds the then applicable Base Target Price or (iii) early termination of this Agreement:

(a) Upon an increase to the Base Target Price, the amount payable for each Margin Milestone in respect of which Contractor’s Margin has previously been paid shall be automatically increased to reflect the applicable milestone percentage of the amount of the increase to the Base Target Price, and the positive difference between such increased amount payable and the amount previously paid shall be invoiced by Contractor to Owner in the next following Request for Payment: provided, however, that any portion of the increase to the Base Target Price that has previously been invoiced to Owner and paid in accordance with clause (c) of this Section 6.3.12 shall be excluded from the application of this clause (a).

 

3


(b) Upon a decrease to the Base Target Price, the amount payable for each Margin Milestone in respect of which Contractor’s Margin has previously been paid shall be automatically decreased to reflect the applicable milestone percentage of the amount of the decrease to the Base Target Price, and the positive difference between the amount previously paid and such decreased amount payable shall be applied as a credit to Owner in the next following Request for Payment.

(c) If at any time the aggregate amount of Direct Costs and Agent for Contract Costs incurred in the performance of Reimbursable Work exceeds the then applicable Base Target Price, payments of Contractor’s Margin for all Margin Milestones shall be recalculated by applying such aggregate amount in place of the Base Target Price in the definition of “Contractor’s Margin”, and the positive difference resulting from such recalculation shall, with respect to each Margin Milestone in respect of which Contractor’s Margin has previously been paid, be invoiced by Contractor to Owner in the next following Request for Payment; provided, however, that the Contractor’s Margin shall not be adjusted pursuant to this clause (c) more than once every [***] days.

(d) If this Agreement is terminated pursuant to and in accordance with Article 31 or Article 32, the amount of Contractor’s Margin owed to Contractor upon such termination shall be calculated on the basis of all Direct Costs and Agent for Contract Costs incurred in the performance of Reimbursable Work prior to the date of such termination rather than the Appendix 1 of Exhibit D Margin Milestone payment schedule. If the amount of Contractor’s Margin calculated pursuant to the preceding sentence is greater or less than the aggregate amount of Contractor’s Margin paid to Contractor prior to the date of such termination, the difference shall be paid to Contractor or Owner, respectively.”

(vi) Exhibit D to the Agreement is hereby amended by deleting Paragraph C therein and inserting the following new Paragraph C it its place:

 

  “C.

Margin Milestones

The Margin Milestones are identified on Appendix 1 to this Exhibit D.”

(vii) Exhibit D to the Agreement is hereby amended by appending a new Appendix 1 thereto in the form attached as Exhibit A to this Amendment.

(viii) Exhibit F to the Agreement is hereby amended by inserting a new Exhibit F-17 immediately following Exhibit F-16, in the form attached as Exhibit B to this Amendment.

 

4


3. Benefits. This Amendment shall inure to the benefit of and be binding upon the Parties and their respective successors and permitted assigns. Except with respect to the rights of successors and permitted assigns as provided in the Agreement, including any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders), nothing express or implied in this Amendment is intended to confer upon any person, other than the Parties and their respective successors and assigns, any rights, remedies, obligations or liabilities under or by reason of this Amendment.

4. Effect of Amendment. Except as specifically set forth herein, the Agreement, as amended by this Amendment, remains in full force and effect in accordance with its terms.

5. Governing Law. This Amendment shall in all respects be governed by, and construed in accordance with the laws of the State of New York without regard to principles of conflicts of laws.

6. Counterparts. This Amendment may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute one and the same instrument. A signed copy of this Amendment transmitted by facsimile or email shall be treated as an original and shall be binding against the Party whose signature appears on such copy.

[signatures appear on following page]

 

5


IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their duly authorized representatives as of the date first written above.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC
By:   /s/ Keith Larson
Name:   Keith Larson
Title:   Secretary

 

KZJV LLC
By:   /s/ Paul Fellows
Name:   Paul Fellows
Title:   Manager
By:   /s/ Matt Key
Name:   Matt Key
Title:   Manager

 

6


Exhibit A

Appendix 1

Margin Milestone Payment Schedule

[Omitted]

 

1


Exhibit B

EXHIBIT F-17

FORM OF CERTIFICATE OF ACHIEVEMENT

[Omitted]

 

1

Exhibit 10.10

(Execution Version)

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER NO. 4

 

Date: October 12, 2022    Change Order No. 4
  

Reference: International to

Domestic Module Fabrication

   Documents: Change Order
   Request as per letter No: PQ-PRM-
   KZV-VGL-LET-00104-22

Venture Global Plaquemines LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware (Owner), and KZJV LLC, a limited liability company duly organized and validly existing under the laws of the State of Texas (Contractor), hereby agree to the following change to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January 7, 2022, by and between Owner and Contractor (as amended, supplemented or otherwise modified, the Agreement). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, agreed upon by the Parties pursuant to Article 12 of the Agreement, is considered an amendment to the Agreement. Except to the extent specifically described in this Change Order, the change(s) set forth herein do(es) not relieve Contractor of its responsibilities set forth in the Agreement.

Provided that this Change Order is executed by both Parties, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Contractor fully for such effects, unless otherwise provided in the detailed description below.

Scope:

Exhibit A (Scope of Work; Applicable Codes and Standards) of the Agreement is hereby amended as follows:

 

  (i)

The sixth sentence of Section 3.4.2 is amended to delete the words “and Indian”.

 

  (ii)

The first sentence of Section 3.5.1 is amended to delete the words “and India”. The third and fifth sentences of Section 3.5.1 are deleted in their entirety.

 

  (iii)

Section 4 is amended to delete the words “Module Fabrication (India) (6 days, 60 hrs/week)” in their entirety.

 

  (iv)

Section 4.3 is amended to delete the words “Balance of piperacks will be fabricated at L&T’s yard in India” and “India fabrication location with 45-day duration included from module loadout date to delivery at the project MOF via ship” in their entirety.

The reference to “[***]” appearing in Exhibit O (Schedule of Major Subcontractors) of the Agreement shall be deleted in its entirety.


(Execution Version)

Price:

This Change Order constitutes compensation in full, and final and complete satisfaction, for the adjustments to the Target Price related to the change in piperack module fabrication location from an international (non-U.S.) piperack module fabrication yard to a domestic (U.S.) piperack module fabrication yard.

 

Initial Target Price:    $[***]
Current Target Price:    $[***]
Value of Change Order:    $[***]
Adjusted Target Price as a result of this Change Order:    $[***]

Deliverable Schedule:

This Change Order shall have no impact on the Project Schedule or Applicable Deadlines.

This Change Order is not valid, except as otherwise provided in the Agreement, until fully executed by Contractor and Owner.

[Signatures on the following page.]


(Execution Version)

IN WITNESS WHEREOF, the Parties have caused this Change Order to be executed by their duly authorized representatives as of the date and year first above written.

 

Venture Global Plaquemines LNG, LLC     KZJV LLC
By:  

/s/ Keith Larson

    By:  

/s/ Pamela C. Roche

Name:   Keith Larson     Name:   Pamela C. Roche
Title:   Secretary     Title:   VP Project Management
      By:  

/s/ Thomas Augustine

      Name:   Thomas Augustine
      Title:   Deputy Project Director

Exhibit 10.11

Execution Version

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

AMENDMENT NO. 2 TO

SECOND AMENDED AND RESTATED

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

THIS AMENDMENT NO. 2 TO SECOND AMENDED AND RESTATED ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Amendment”), entered into effective as of February 1, 2023 (the “Effective Date”), is entered into by and between VENTURE GLOBAL PLAQUEMINES LNG, LLC, a Delaware limited liability company (“Owner”), and KZJV LLC, a Texas limited liability company (“Contractor”).

WITNESSETH

WHEREAS, Owner and Contractor are parties to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement dated as of January 7, 2022, as amended by Amendment No. 1 dated as of October 11, 2022 (the “Agreement”); and

WHEREAS, pursuant to Section 41.8 of the Agreement, the Parties desire to amend the Agreement as set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants and provisions herein contained, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby covenant and agree as follows:

1. Defined Terms. Capitalized terms not defined in this Amendment shall have the meaning given to such terms in the Agreement.

2. Amendments. Effective as of the Effective Date, the Agreement is hereby amended as follows:

(i) Article 1 of the Agreement is hereby amended to delete the defined terms “Net LNG Sales Proceeds” and “Pre-Commercial Production Period” in their entirety.

(ii) Article 1 of the Agreement is hereby amended to delete the defined terms “Applicable Deadline”, “Base Target Price”, “Contractor’s G&A”, “Contractor’s Margin”, “Major Subcontract” and “Total Cost Exclusions” and insert the following new defined terms in their place:

““Applicable Deadline” means (i) an LNG Production System Substantial Completion Deadline, the Facility Substantial Completion Deadline or the Final Completion Deadline, as applicable and (ii) solely for the purposes of the definitions of “Change Order”, “Critical Path” and (only to the extent contemplated in Appendix 2 of Exhibit D) “Owner Caused Delay” and Sections 12.1.8, 12.2.3, 12.5 and the second sentence of Section 16.1, a Completion Date associated with an Interim Milestone, a Primary Milestone or a Super Primary Milestone.

 

1


Base Target Price” means, as of any date, an amount equal to the sum of the Direct Costs (other than Tax Costs) and Agent for Contracts Costs (other than Tax Costs) components of the Target Price as of such date.

Contractor’s G&A” means, in respect of each month that Contractor is eligible for reimbursement of Direct Costs or is managing Agent For Contractor Work, Contractor’s general and administrative expenses for such month, which shall be a fixed percentage during the term hereof and equal at all times to (i) [***] of the sum of the amount of Direct Costs (other than Tax Costs) that are reimbursable to Contractor and the Agent For Contracts Costs (other than Tax Costs) in respect of such month plus (ii) [***] of the sum of the amount of Tax Costs that are reimbursable to Contractor in respect of such month, all as specifically defined in Exhibit B.

Major Subcontract” means (a) any Subcontract providing services or Materials for the Work having an aggregate value in excess of [***], (b) multiple Subcontracts with the same Subcontractor (including any Subcontractor that is an Affiliate of Contractor) providing services or Materials for the Work having an aggregate value in excess of [***]; provided that, for the purposes of Sections 6.3.3, 6.7, 19.4.1(i) and 23.1.1, “Major Subcontract” means any Subcontract providing services or Materials for the Work having an aggregate value in excess of [***].

Total Cost Exclusions means for the purposes of Section 8.1.2: (i) all or any portion of a Schedule Bonus paid to or forfeited by Contractor as described in Article 7; (ii) Taxes, if paid by Contractor which will then be reimbursed by Owner, unless such Taxes constitute Non-Reimbursable Costs; (iii) costs incurred by Contractor or assigned by Owner with respect to Owner Furnished Equipment and Materials, including with respect to defects or deficiencies, or lack of performance of, Owner Furnished Equipment and Materials; (iv) uninsured losses and deductibles arising under the Construction and Erection All Risk Insurance Policy, Owner Controlled Insurance Program for Commercial General Liability Policy, marine cargo, and any permanent property insurance policy, each procured by Owner; (v) Direct Costs paid to or paid by Contractor for Work subject to a claim against the Builder’s Risk Insurance Policy, Owner Controlled Insurance Program for Commercial General Liability Policy Marine Cargo, or Permanent Property Insurance policies; (vi) amounts reimbursed or credited to Contractor by Subcontractors (including back charges for Work performed by Contractor to complete Subcontractor work or remedy Subcontractor Defects and Deficiencies, liquidated damages or otherwise); and (vii) any other cost expressed to be excluded from the calculation of Total Costs hereunder; provided that, in the case of Defects or Deficiencies, the Direct Costs paid to Contractor or costs incurred by Owner in order to correct the Defects or Deficiencies in accordance with Section 20.5 be included in the calculation of “Total Costs”.”

 

2


(iii) Article 1 of the Agreement is hereby amended to insert the following new defined terms in alphabetical order:

““Certificate of Schedule Milestone Achievement” means the certificate, in substantially the form set forth as Exhibit F-18, to be provided by Contractor confirming in writing that the particular Schedule Milestone has been achieved and explaining how it was achieved.

Completion Date” means, with respect to any Schedule Milestone, the date for completion of such Schedule Milestone set forth on Appendix 2 of Exhibit D.

Interim Milestone” means a Schedule Milestone identified as an Interim Milestone on Appendix 2 of Exhibit D.

Interim Milestone Bonus” means a bonus payment in an amount equal to [***], as such amount may be adjusted pursuant to Sections 7.1.2 and 7.1.3.

Phase 2 Agreement” means that certain Engineering, Procurement and Construction Agreement, dated as of January 10, 2023, between Owner and Contractor.

Primary Milestone” means a Schedule Milestone identified as a Primary Milestone on Appendix 2 of Exhibit D.

Primary Milestone Bonus” means a bonus payment in an amount equal to [***], as such amount may be adjusted pursuant to Sections 7.2.2 and 7.2.3.

Schedule Bonus” means an Interim Milestone Bonus, a Primary Milestone Bonus or a Super Primary Milestone Bonus, as applicable.

Schedule Bonus Cap” means [***].

Schedule Milestone” an event to be achieved by Contractor for payment of a Schedule Bonus pursuant to and in accordance with Article 7, as described on Appendix 2 of Exhibit D.

Super Primary Milestone” means a Schedule Milestone identified as a Super Primary Milestone on Appendix 2 of Exhibit D.

 

3


Super Primary Milestone Bonus” means a bonus payment in an amount equal to [***], as such amount may be adjusted pursuant to Sections 7.3.2 and 7.3.3.

Tax Costs” means any sales tax or sales and use tax levied by any U.S. state or any political subdivision thereof that is incurred by Contractor or any Agent For Contractor in the performance of the Work or the Agent for Contracts Work.”

(iv) Section 6.1.2 of the Agreement is hereby deleted in its entirety and the following new Section 6.1.2 shall be inserted in its place:

“6.1.2 Contractor has satisfied itself as to (i) the correctness and sufficiency of the Target Price for the purposes of the waiver of any increase as described in Section 3.1.2 and (ii) the sufficiency of the Target Price for giving effect to the provisions of Article 8. The Target Price includes the estimated costs for the Materials, labor, transportation, services and Intellectual Property rights forming part of the Reimbursable Work and, including the costs of Materials, transportation and storage of Materials and all Taxes other than sales and use taxes, duties and tariffs for which Contractor is responsible hereunder, the cost to Contractor to provide the Performance Security, and Contractor’s estimated cost for repair or replacement of all Defects and Deficiencies and other corrective Work prior to the commencement of the Warranty Period, including as described in Exhibit B.”

(v) Section 6.3.12 of the Agreement is hereby deleted in its entirety and the following new Section 6.3.12 shall be inserted in its place:

“6.3.12 The Parties acknowledge that the amount of Contractor’s Margin payable by Owner in respect of each Margin Milestone is calculated based on a percentage of the then applicable Base Target Price. The following methodology will be applied with respect to any (i) adjustment to the Base Target Price after the Effective Date, (ii) instance where the aggregate amount of Direct Costs (other than Tax Costs) and Agent for Contract Costs (other than Tax Costs) incurred in the performance of the Reimbursable Work exceeds the then applicable Base Target Price or (iii) early termination of this Agreement:

(a) Upon an increase to the Base Target Price, the amount payable for each Margin Milestone in respect of which Contractor’s Margin has previously been paid shall be automatically increased to reflect the applicable milestone percentage of the amount of the increase to the Base Target Price, and the positive difference between such increased amount payable and the amount previously paid shall be invoiced by Contractor to Owner in the next following Request for Payment; provided, however, that any portion of the increase to the Base Target Price that has previously been invoiced to Owner and paid in accordance with clause (c) of this Section 6.3.12 shall be excluded from the application of this clause (a).

 

4


(b) Upon a decrease to the Base Target Price, the amount payable for each Margin Milestone in respect of which Contractor’s Margin has previously been paid shall be automatically decreased to reflect the applicable milestone percentage of the amount of the decrease to the Base Target Price, and the positive difference between the amount previously paid and such decreased amount payable shall be applied as a credit to Owner in the next following Request for Payment.

(c) If at any time the aggregate amount of Direct Costs and Agent for Contract Costs incurred in the performance of Reimbursable Work exceeds the then applicable Base Target Price, payments of Contractor’s Margin for all Margin Milestones shall be recalculated by applying such aggregate amount in place of the Base Target Price in the definition of “Contractor’s Margin”, and the positive difference resulting from such recalculation shall, with respect to each Margin Milestone in respect of which Contractor’s Margin has previously been paid, be invoiced by Contractor to Owner in the next following Request for Payment; provided, however, that the Contractor’s Margin shall not be adjusted pursuant to this clause (c) more than once every ninety (90) days.

(d) If this Agreement is terminated pursuant to and in accordance with Article 31, the amount of Contractor’s Margin owed to Contractor upon such termination shall be calculated on the basis of all Direct Costs (other than Tax Costs) and Agent for Contract Costs (other than Tax Costs) incurred in the performance of Reimbursable Work prior to the date of such termination rather than the Appendix 1 of Exhibit D Margin Milestone payment schedule. If the amount of Contractor’s Margin calculated pursuant to the preceding sentence is greater or less than the aggregate amount of Contractor’s Margin paid to Contractor prior to the date of such termination, the difference shall be paid to Contractor or Owner, respectively.”

(vi) Article 7 of the Agreement is hereby deleted in its entirety and the following new Article 7 shall be inserted in its place:

“7. SCHEDULE BONUSES

7.1 INTERIM MILESTONE BONUSES

7.1.1 In consideration for Contractor’s timely completion of the Work, Owner will, subject to Section 7.4, pay to Contractor, not later than [***] days following the date of achievement, in addition to the amounts payable to Contractor pursuant to Section 6.3, an Interim Milestone Bonus in respect of each corresponding Interim Milestone that Contractor has achieved prior to, on, or within [***] following the relevant Completion Date.

 

5


7.1.2 If Contractor achieves an Interim Milestone prior to the relevant Completion Date, the amount of the Interim Milestone Bonus payable in respect of such Interim Milestone shall be increased by an amount equal to [***] for each day between the date of such achievement and such Completion Date.

7.1.3 If Contractor achieves an Interim Milestone after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Interim Milestone Bonus payable in respect of such Interim Milestone shall be equal to [***]. If Contractor achieves an Interim Milestone more than [***] after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Interim Milestone Bonus payable in respect of such Interim Milestone shall be equal to [***]. If Contractor achieves an Interim Milestone more than [***] after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Interim Milestone Bonus payable in respect of such Interim Milestone shall be equal to [***]. For the avoidance of doubt, if Contractor does not achieve an Interim Milestone within [***] Days of the relevant Completion Date, no Interim Milestone Bonus shall be payable in respect of such Interim Milestone.

7.2 PRIMARY MILESTONE BONUSES

7.2.1 In consideration for Contractor’s timely completion of the Work, Owner will, subject to Section 7.4, pay to Contractor, not later than [***] following the Final Completion Date, in addition to the amounts payable to Contractor pursuant to Section 6.3, a Primary Milestone Bonus in respect of each corresponding Primary Schedule Milestone that Contractor has achieved prior to, on, or within [***] following the relevant Completion Date.

7.2.2 If Contractor achieves a Primary Milestone prior to the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be increased by an amount equal to [***] for each day between the date of such achievement and such Completion Date.

 

6


7.2.3 If Contractor achieves a Primary Milestone after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. For the avoidance of doubt, if Contractor does not achieve a Primary Milestone within [***] of the relevant Completion Date, no Primary Milestone Bonus shall be payable in respect of such Primary Milestone.

7.3 SUPER PRIMARY MILESTONE BONUSES

7.3.1 In consideration for Contractor’s timely completion of the Work, Owner will, subject to Section 7.4, pay to Contractor, not later than [***] following the Final Completion Date, in addition to the amounts payable to Contractor pursuant to Section 6.3, a Super Primary Milestone Bonus in respect of each corresponding Super Primary Schedule Milestone that Contractor has achieved prior to, on, or within [***] following the relevant Completion Date.

7.3.2 If Contractor achieves a Super Primary Milestone prior to the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be increased by an amount equal to [***] for each day between the date of such achievement and such Completion Date.

7.3.3 If Contractor achieves a Super Primary Milestone after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than [***] after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than

 

7


[***] after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than [***] after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than [***] after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. For the avoidance of doubt, if Contractor does not achieve a Super Primary Milestone within [***] of the relevant Completion Date, no Super Primary Milestone Bonus shall be payable in respect of such Super Primary Milestone.

7.4 LIMITATIONS

7.4.1 Owner’s total liability to Contractor under this Article 7 shall not exceed the Schedule Bonus Cap.

7.4.2 Notwithstanding anything contained herein to the contrary, if at any time Contractor’s Margin is reduced pursuant to Section 8.2 to:

 

  (a)

[***], then the aggregate amount of all Schedule Bonuses in respect of which Contractor has been paid or is entitled to be paid shall be reduced by an amount equal to [***] of such aggregate amount;

 

  (b)

[***], then the aggregate amount of all Schedule Bonuses in respect of which Contractor has been paid or is entitled to be paid shall be reduced by an amount equal to [***] of such aggregate amount;

 

  (c)

[***], then the aggregate amount of all Schedule Bonuses in respect of which Contractor has been paid or is entitled to be paid shall be reduced by an amount equal to [***] of such aggregate amount;

 

  (d)

[***], then the aggregate amount of all Schedule Bonuses in respect of which Contractor has been paid or is entitled to be paid shall be reduced by an amount equal to [***] of such aggregate amount;

 

8


provided that, for the avoidance of doubt, the reductions described in this Section 7.4.2 shall not be cumulative. If Owner has paid any Schedule Bonus(es) to Contractor prior to such reduction, then Owner may, without prejudice to Section 41.7, deduct from any amounts owed to Contractor hereunder an amount equal to the amount of such reduction.

7.4.3 Notwithstanding anything contained herein to the contrary, if Owner determines that Contractor has not or will not be entitled to payment for any Primary Milestone or Super Primary Milestone pursuant to and in accordance with Section 7.2 and Section 7.3, respectively, Owner shall have no obligation to pay to Contractor any Schedule Bonuses pursuant to this Agreement. If Owner has paid any Schedule Bonus(es) to Contractor prior to such determination, then Owner may, without prejudice to Section 41.7, deduct from any amounts owed to Contractor hereunder an amount equal to the aggregate amount of all such Schedule Bonuses previously paid.

7.4.4 For the avoidance of doubt, Contractor shall not be entitled to payment in respect of any Schedule Bonus unless and until the achievement of the relevant Schedule Milestone is confirmed by a Certificate of Schedule Milestone Achievement to be provided by Contractor together with the relevant Request for Payment.”

(vii) Section 8.2.1 of the Agreement is hereby deleted in its entirety and the following new Section 8.2.1 shall be inserted in its place:

“8.2.1 In the event that at any time a Cost Overrun exists that is greater than [***], Owner shall be permitted by written notice to Contractor to reduce the Contractor’s Margin for all purposes hereunder as follows:

(a) if the Cost Overrun is greater than [***], but less than or equal to [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***];

(b) if the Cost Overrun is greater than [***], but less than or equal to [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***];

(c) if the Cost Overrun is greater than [***], but less than or equal to [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***]; and

(d) if the Cost Overrun is greater than [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***].”

 

9


(viii) Section 8.2.3 of the Agreement is hereby deleted in its entirety and the following new Section 8.2.3 shall be inserted in its place:

“8.2.3 Within thirty (30) days following the Final Completion Date, Owner shall calculate and deliver to Contractor written notice of the amount by which the Total Costs exceed the Target Price, if any, as of the Final Completion Date, such notice to include Owner’s supporting calculations of the amount of such excess.”

(ix) Section 8.3.1 of the Agreement is hereby deleted in its entirety and the following new Section 8.3.1 shall be inserted in its place:

“8.3.1 Within thirty (30) days following the Final Completion Date, Owner shall calculate and deliver to Contractor written notice of the Cost Savings, if any, such notice to include Owner’s supporting calculations of the amount of the Cost Savings. The Cost Savings shall be calculated as of the Final Completion Date. If there is a Cost Savings that is greater than [***], Owner shall make payment of the following amount to Contractor within [***] days of Owner’s delivery of written notice to Contractor:

(a) if the Cost Savings is greater than [***], but less than or equal to [***], an amount equal to [***] of the amount of the Cost Savings;

(b) if the Cost Savings is greater than [***], but less than or equal to [***], an amount equal to [***] of the amount of the Cost Savings;

(c) if the Cost Savings is greater than [***], but less than or equal to [***], an amount equal to [***] of the amount of the Cost Savings; and

(d) if the Cost Savings is greater than [***], an amount equal to [***] of the amount of the Cost Savings.”

 

10


(x) Section 12.1.1 of the Agreement is hereby deleted in its entirety and the following new Section 12.1.1 shall be inserted in its place:

“12.1.1. Owner may at any time order changes to the Work. Contractor may propose changes to the Work for Owner’s consideration; provided that Owner shall not be obligated to approve any such change. Contractor shall be entitled to receive a Change Order in accordance with the provisions of Section 12.1.2 with respect to: (a) Force Majeure Events; (b) Owner Caused Delays; (c) Owner-directed or approved changes; (d) an act, omission or failure by Owner (in its capacity as owner under the Phase 2 Agreement) under the Phase 2 Agreement or an act, omission or failure by any party for which Owner (in such capacity) is responsible with respect to the Phase 2 Facility that demonstrably and adversely affects Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule under this Agreement (except in each case to the extent such affects on Contractor’s costs and/or ability to perform has already been addressed through an executed change order under the Phase 2 Agreement); (e) any failure by an Owner Contractor to perform its material obligations under the relevant Owner Contract that demonstrably and adversely affects Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule; (f) any error, inaccuracy or omission in or change by Owner to the Relied Upon Information that demonstrably and adversely affects Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule; (g) as provided elsewhere in this Agreement including in Sections 4.1.4, 12.4 and 16.3.2; (h) Pre-Existing Hazardous Substances which demonstrably and adversely impact Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule (except to the extent any additional costs or delay is the result of Contractor’s, its Subcontractors’ or Agent For Contractor’s Grossly Negligent act or omission or Willful Misconduct in the handling, storage or transportation of any Pre-Existing Hazardous Substance after discovery by Contractor, a Subcontractor or Agent For Contractor); (i) suspensions in the Work in accordance with Section 17.1.1 or Section 17.1.3; (j) a Carrollton Gage Delay; (k) any soils improvement cement reagent adjustment; and (l) any impact described in clauses (c), (f), (h) or (k) that arises under or relates to “Work” (as that term is defined under the Phase 2 Agreement) under the Phase 2 Agreement (except in each case to the extent such impact has already been addressed through an executed change order under the Phase 2 Agreement); provided that, with respect BH Testing Delay, the Change Order which shall be limited to a day-for-day extension of the applicable LNG Production System Substantial Completion Date or the Facility Substantial Completion Date, as the case may be, equal to the number of days of such BH Testing Delay.”

(xi) Section 21.1 of the Agreement is hereby amended by deleting the words “of Net LNG Sales Proceeds or” in their entirety.

(xii) Section 22.2.1 of the Agreement is hereby amended by deleting clause (b) and clause (c) thereof in their entirety.

 

11


(xiii) Exhibit B-1 to the Agreement is hereby amended by deleting the first two sentences of Section 3 thereof and inserting the following text in their place:

“A multiplier of (i) [***] for all Direct Costs (other than Tax Costs) and (ii) [***] for all Tax Costs (each, a “G&A Multiplier”) will be applied across all such Direct Costs for G&A recovery. The applicable G&A Multiplier will recover the following applicable overhead costs:”

(xiv) Exhibit C to the Agreement is hereby deleted in its entirety and a new Exhibit C in the form attached as Attachment C to this Amendment shall be inserted in its place.

(xv) Exhibit D to the Agreement is hereby amended by appending a new Appendix 2 thereto in the form attached as Attachment A to this Amendment.

(xvi) Exhibit F to the Agreement is hereby amended by inserting a new Exhibit F-18 immediately following Exhibit F-17, in the form attached as Attachment B to this Amendment.

(xvii) Appendix Y-1 to Exhibit Y to the Agreement is hereby deleted in its entirety and a new Appendix Y-1 in the form attached as Attachment D to this Amendment shall be inserted in its place.

3. Benefits. This Amendment shall inure to the benefit of and be binding upon the Parties and their respective successors and permitted assigns. Except with respect to the rights of successors and permitted assigns as provided in the Agreement, including any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders), nothing express or implied in this Amendment is intended to confer upon any person, other than the Parties and their respective successors and assigns, any rights, remedies, obligations or liabilities under or by reason of this Amendment. 

4. Effect of Amendment. Except as specifically set forth herein, the Agreement, as amended by this Amendment, remains in full force and effect in accordance with its terms.

5. Governing Law. This Amendment shall in all respects be governed by, and construed in accordance with the laws of the State of New York without regard to principles of conflicts of laws.

6. Counterparts. This Amendment may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute one and the same instrument. A signed copy of this Amendment transmitted by facsimile or email shall be treated as an original and shall be binding against the Party whose signature appears on such copy.

[signatures appear on following page]

 

12


IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their duly authorized representatives as of the Effective Date.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC
By:   /s/ Keith Larson
Name:   Keith Larson
Title:   Secretary

 

KZJV LLC
By:   /s/ Paul Fellows
Name:   Paul Fellows
Title:   Manager

 

By:   /s/ Matt Key
Name:   Matt Key
Title:   Manager

 

13


Attachment A

Exhibit D – Appendix 2

Schedule Milestones

[Omitted]

 

1


Attachment B

EXHIBIT F-18

FORM OF CERTIFICATE OF SCHEDULE MILESTONE ACHIEVEMENT

[Omitted]

 

1


Attachment C

EXHIBIT C

CONTRACTOR RATES

[Omitted]

 

2


Attachment D

APPENDIX Y-1

PERSONNEL ASSIGNMENT AUTHORIZATION FORM

[Omitted]

 

1

Exhibit 10.12

(Execution Version)

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER NO. 5

 

  Date: March 2, 2023      Change Order No. 5
       Reference: Scope Additions,
       Deletions and Modifications
       Documents: Change Order
       Notices and Change Order
       Requests as per letters No: PQ-
       PRM-KZV-VGL-LET-00029,
       PQ-PRM-KZV-VGL-LET-
       00031, PQ-PRM-KZV-VGL-
       LET-00032, PQ-PRM-KZV-
       VGL-LET-00033, PQ-PRM-
       KZV-VGL-LET-00040, PQ-
       PRM-KZV-VGL-LET-00041,
       PQ-PRM-KZV-VGL-LET-
       00042, PQ-PRM-KZV-VGL-
       LET-00043, PQ-PRM-KZV-
       VGL-LET-00044, PQ-PRM-
       KZV-VGL-LET-00046, PQ-
       PRM-KZV-VGL-LET-00049,
       PQ-PRM-KZV-VGL-LET-
       00054, PQ-PRM-KZV-VGL-
       LET-00055, PQ-PRM-KZV-
       VGL-LET-00060, PQ-PRM-
       KZV-VGL-LET-00062, PQ-
       PRM-KZV-VGL-LET-00067-22,
       PQ-PRM-KZV-VGL-LET-00069
       -22, PQ-PRM-KZV-VGL-LET-
       00072-22, PQ-PRM-KZV-VGL-
       LET-00080-22, PQ-PRM-KZV-
       VGL-LET-00082-22, PQ-PRM-
       KZV-VGL-LET-00085-22,
       PQ-PRM-KZV-VGL-LET-00087
       -22, PQ-PRM-KZV-VGL-LET-
       00100-22, PQ-PRM-KZV-VGL-
       LET-00107-22, PQ-PRM-KZV-
       VGL-LET-00108-22, PQ-PRM-
       KZV-VGL-LET-00109-22, PQ-
       PRM-KZV-VGL-LET-00123-22,
       PQ-PRM-KZV-VGL-LET-
       00124-22, PQ-PRM-KZV-VGL-
       LET-00125-22, PQ-PRM-KZV-
       VGL-LET-00130-22, PQ-PRM-
       KZV-VGL-LET-00131-22, PQ-
       PRM-KZV-VGL-LET-00132-22,
       and PQ-PRM-KZV-VGL-LET-
       00133-22


Venture Global Plaquemines LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware (“Owner”), and KZJV LLC, a limited liability company duly organized and validly existing under the laws of the State of Texas (“Contractor”), hereby agree to the following changes to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January 7, 2022, by and between Owner and Contractor (as amended, supplemented or otherwise modified, the “Agreement”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, agreed upon by the Parties pursuant to Article 12 of the Agreement, is considered an amendment to the Agreement. Except to the extent specifically described in this Change Order, the changes set forth herein do not relieve Contractor of its responsibilities or Owner of its reimbursement obligations for all Reimbursable Costs as set forth in the Agreement.

Provided that this Change Order is executed by both Parties, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Contractor fully for such effects, unless otherwise provided in the detailed description below.

Scope:

Exhibit A (Scope of Work; Applicable Codes and Standards) of the Agreement is hereby amended as follows:

 

  (1)

The items listed in Table 1 below are incorporated in the scope of Work and further defined in the change proposals referenced therein and submitted by Contractor under the cover of the subject letter reference number. The scope of the activities described in the subject change proposals, notice references or Project Deviation Notices (PDN) listed in Table 1 are provided as reference as to the activities to be performed in this Change Order. Contractor shall perform all related Work noted in the subject Notice of Change letter referenced, to include, but not be limited to, any related PDNs listed herein even if not yet formally submitted to Owner, without exclusion.


Table 1

 

VG
PCO
No.
  

Notice

Ref.

   KZJV
Change
Proposal
No.
   KZJV
Rev
No.
   KZJV
PDN
No.
  

Description

   Target Price
Change Amount
[***]    [***]    [***]    [***]    [***]    LNG loading lines – Pipe-in-Pipe    [***]
[***]    [***]    [***]    [***]    [***]    Plant Capacity Optimization    [***]
[***]    [***]    [***]    [***]    [***]    Improve Soil Under Heavy Haul Road (HHR) South of LA23 for New UOP Modules Sizes and Weights    [***]
[***]    [***]    [***]    [***]    [***]    Camera Towers    [***]
[***]    [***]    [***]    [***]    [***]    Refrigerant System    [***]
[***]    [***]    [***]    [***]    [***]    Thermal Modeling    [***]
[***]    [***]    [***]    [***]    [***]    EPC Target Price Adjustment for Cement above Design Mix based on actuals through 31 July 2022    [***]
[***]    [***]    [***]    [***]    [***]    New potable water tank and river water treatment package    [***]
[***]    [***]    [***]    [***]    [***]    Aggregate Supply Chain Cost Increase – to 31-Aug-2022    [***]
[***]    [***]    [***]    [***]    [***]    Additional sheet piling wall for east construction zone    [***]
[***]    [***]    [***]    [***]    [***]    HHC Treating System design    [***]
[***]    [***]    [***]    [***]    [***]    Electrical Grid Configuration Finalization    [***]
[***]    [***]    [***]    [***]    [***]    Seismic monitoring system for LNG storage tanks    [***]


[***]    [***]          [***]    Temporary Construction Water System- Supplement to VG provided water    [***]
[***]    [***]          [***]    Temporary Water    [***]
[***]    [***]    [***]    [***]    [***]    Letter of Credit Fees for Change Orders #1-4    [***]
[***]    [***]    [***]    [***]    [***]    Beard Activities to Accelerate Schedule    [***]
[***]    [***]    [***]    [***]    [***]    Removal of Start-up BOG Compressor    [***]
[***]    [***]          [***]    4 Plex    [***]
[***]    [***]          [***]    Adding of a 25 Cubic Yard Covered Roll Off Dumpster    [***]
[***]    [***]          [***]    IT Support ABS Install on VG Trailers (T&M)    [***]
[***]    [***]          [***]    IT Support ABS Install on VG Trailers (Triad Comms. LS)    [***]
[***]    [***]          [***]    Added duct bank for GIS Building    [***]
[***]    [***]          [***]    Removal of aluminum steps purchase    [***]
[***]    [***]          [***]    Welding the final hold-down clips to the pile cap/marine mod and WM DoR    [***]
[***]    [***]          [***]    OFE Barge and Ship Loose Materials    [***]
[***]    [***]          [***]    Painting required for all uninsulated SS piping & equipment    [***]
[***]    [***]          [***]    Separate Protection and Control Relays / E-House & Substation Equipment Tagging    [***]
[***]    [***]          [***]    GIS Building Overpressure Design    [***]
[***]    [***]          [***]    Operator Training Simulator    [***]
[***]    [***]          [***]    EMS for EDG System    [***]
[***]    [***]          [***]    Zylan Coating Bolts    [***]
[***]    [***]          [***]    RO Demin Package    [***]


[***]    [***]          [***]    Feed gas / HC condensate system ESD & blowdown valves    [***]
[***]    [***]          [***]    DOR adds and deletes related to the WMJV Marine Scope    [***]
[***]    [***]          [***]    State HWY 23 Roadside Drainage    [***]
[***]    [***]          [***]    Liners for all concrete sumps    [***]
[***]    [***]          [***]    Deluge valves for Liquefaction    [***]
[***]    [***]          [***]    BOD & VG Philosophies    [***]
[***]    [***]          [***]    Temporary storm water discharge diffusers    [***]
[***]    [***]          [***]    Removal of Jetty OWS and adjustment of jetty curbing    [***]
[***]    [***]          [***]    PCSW Additional Work    [***]
[***]    [***]          [***]    Increase the warm flare header piping from 24” to 30”    [***]
[***]    [***]          [***]    Fire Water Philosophy Meetings    [***]
[***]    [***]          [***]    Client Comment Log    [***]
[***]    [***]          [***]    FW Piping in Northwest Area    [***]
[***]    [***]          [***]    Shoreline Isolation Valves    [***]
[***]    [***]          [***]    STG Interface and Layout    [***]
[***]    [***]          [***]    KZJV Update of PTS H&MBs    [***]
[***]    [***]          [***]    LNG Storage Tank 40’ Interconnect Piperack Section and P&ID comment on line size / number changes    [***]
[***]    [***]          [***]    PLC Supplier    [***]
[***]    [***]          [***]    Foundation elevation    [***]
[***]    [***]          [***]    Increased line / equipment for two GTs for start-up SIMOPS    [***]
[***]    [***]          [***]    U/G electrical trenches in lieu of direct bury    [***]
[***]    [***]          [***]    Additional LNG Rundown Surge Analysis    [***]


[***]    [***]          [***]    408 Permit Alignment for foundations, structures & site prep    [***]
[***]    [***]          [***]    Locate and prepare cement/aggregate unloading areas closer to the jobsite    [***]
[***]    [***]          [***]    Seismic Specification    [***]
[***]    [***]          [***]    Wind Specification    [***]
[***]    [***]          [***]    Temporary Construction Drainage - LNG Storage Tank Area    [***]
[***]    [***]          [***]    Exchangers - Client Comments    [***]
[***]    [***]          [***]    Overall Mechanical Lead Position    [***]
[***]    [***]          [***]    Even pass for Tempered and PIS Tempered water cooler    [***]
[***]    [***]          [***]    Nitrogen system capacity increase    [***]
[***]    [***]          [***]    Aqueous Ammonia Dispersion Study    [***]
[***]    [***]          [***]    LTS LNG Trench Fire Analysis    [***]
[***]    [***]          [***]    CSE Workhour Budget    [***]
[***]    [***]          [***]    SPCC Update    [***]
[***]    [***]          [***]    Additional client comments to Exchangers specs    [***]
[***]    [***]          [***]    Additional client comments to Machinery specs    [***]
[***]    [***]          [***]    Process Flare Study and Datasheet Comment Support    [***]
[***]    [***]          [***]    Piping GLPS/PSUP Training    [***]
[***]    [***]          [***]    IFR H&MBs    [***]
[***]    [***]          [***]    Additional cases—IFD H&MBs    [***]
[***]    [***]          [***]    Additional IFD H&MBs (UOP Data)    [***]
[***]    [***]          [***]    IFR BODs    [***]
[***]    [***]          [***]    Additional IFD BODs    [***]
[***]    [***]          [***]    VG Hydraulics Review    [***]
[***]    [***]          [***]    Issue Hydraulics Formally    [***]
[***]    [***]          [***]    VG PRV Calc Review    [***]


[***]    [***]          [***]    Issue PRV Calcs Formally    [***]
[***]    [***]          [***]    PIS Support    [***]
[***]    [***]          [***]    Instrument Air Study Support    [***]
[***]    [***]          [***]    BOP Flarenet Model    [***]
[***]    [***]          [***]    Extra HAZOP Support    [***]
[***]    [***]          [***]    Acid Gas Header Line Size    [***]
[***]    [***]          [***]    Evaluation of 5 proposals for Hot Oil Heaters (MB801)    [***]
[***]    [***]          [***]    Furnace Environmental issues associated with Permit Details    [***]
[***]    [***]          [***]    Additional Leadership to Support Schedule    [***]
[***]    [***]          [***]    RFI Coordinator Addition    [***]
[***]    [***]          [***]    Additional Model Manager Support for OFE Data    [***]
[***]    [***]          [***]    Additional HOC Doc Mgmt resource to support use of Hexagon    [***]
[***]    [***]          [***]    Procurement Resources for T&C’s Review (exceptions log)    [***]
[***]    [***]          [***]    S&C and Capitol Spare Part Log    [***]
[***]    [***]          [***]    Exhibit X - Procurement Support    [***]
[***]    [***]          [***]    Procurement Status Report - Re-Baseline    [***]
[***]    [***]          [***]    Additional Security Fencing- Levee (move to AFC?)    [***]
[***]    [***]          [***]    Firewater Platform Layout    [***]
[***]    [***]          [***]    PTS Fire & Gas Location Plans    [***]
[***]    [***]          [***]    Sigma Thermal packaged heater solution    [***]
[***]    [***]          [***]    Slop water recovery    [***]
[***]    [***]          [***]    Air Cooled Condenser - EVAPCO Risk Mitigation Plan    [***]
[***]    [***]          [***]    Booster Compressor recycle tie-in    [***]
[***]    [***]          [***]    Revised Material per MSD for Freed Gas Heater    [***]


[***]    [***]          [***]    Instrumentation Addition to Environmental Systems    [***]
[***]    [***]          [***]    Addition of Pump to BOG and Steam Turbine Oily Water Sumps    [***]
[***]    [***]          [***]    External Splitter Box    [***]
[***]    [***]          [***]    Additional Spill Containment Sump and Pumps    [***]
[***]    [***]          [***]    Miscellaneous Environmental Variances    [***]
[***]    [***]          [***]    Warm Flare Area Changes    [***]
[***]    [***]          [***]    Regularly Scheduled PCSW Meetings/Workshop with VG    [***]
[***]    [***]          [***]    Process data for Offline instrument    [***]
[***]    [***]          [***]    GE PIS P&ID Drafting    [***]
[***]    [***]          [***]    VG not approving Supplier Recommendation for ASME Pumps    [***]
[***]    [***]          [***]    VG Management of Change System    [***]
[***]    [***]          [***]    Material Management Software Purchase and Corresponding Workhours Adjustment    [***]
[***]    [***]          [***]    Capacity Optimization LPS4 - addressed in PDN-0070    [***]
[***]    [***]          [***]    Critical Vendor Data Report    [***]
[***]    [***]          [***]    Procurement & Materials Information - Data Management    [***]
[***]
  

[***]

         [***]   

Design Basis for 111-700-PV- 110113 (BOG PV to LP Flare)

   [***]
[***]   

[***]

         [***]   

PV from BOG Header to LP Flare.

   [***]
[***]    [***]          [***]    Temporary Construction Water System- scope award to Rain4Rent    [***]
[***]    [***]          [***]    Entergy Tie-in ($1M each phase, EPC scope)    [***]
[***]    [***]          [***]    SH23 U-Turn and Deceleration Lane    [***]
[***]    [***]          [***]    Soft Starter for BOG Compressor Motors    [***]


[***]    [***]          [***]    Subsonic Flares    [***]
[***]    [***]          [***]    Information Request - foundation piles for the stormwater pipes on the south side    [***]
[***]    [***]          [***]    Wind speed requirements    [***]
[***]    [***]          [***]    Entergy tie-in to distribution system    [***]
[***]    [***]          [***]    Piping Agreement Impacts- global supply-restricted AML-critic    [***]
[***]    [***]          [***]    Noise Mitigations    [***]
[***]    [***]          [***]    Add indication and pre-alarm to all SIS transmitters    [***]
[***]    [***]          [***]    Change Instrument Tag Numbers    [***]
[***]    [***]          [***]    Analyzer System Scope Changes    [***]
[***]    [***]          [***]    Cryogenic Containment Trough - Expediting & Inspection    [***]
[***]    [***]          [***]    Procurement Status Report - Re-Baseline II    [***]
[***]    [***]          [***]    SharePoint Procurement Deliverables    [***]
[***]    [***]          [***]    HAZOP Action - the Hot Oil System Design Temp Increase    [***]
[***]    [***]          [***]    Additional Revisions to Safety Drawings    [***]
[***]    [***]          [***]    Revised Tagging and Document numbering of Vertical Pumps    [***]
[***]    [***]    [***]    [***]    [***]    Update to BOG compressor pricing    [***]
[***]    [***]    [***]    [***]    [***]    IFH P&ID Issue    [***]
[***]    [***]    [***]    [***]    [***]    Plantwide Dynamic Model    [***]
[***]    [***]    [***]    [***]    [***]    Larger Amine Storage Tank    [***]


[***]    [***]    [***]    [***]    [***]    Sump and Pump for Chemical Canopy    [***]
[***]    [***]    [***]    [***]    [***]    FW Test Pump Changes    [***]
[***]    [***]    [***]    [***]    [***]    Feed Gas Heater    [***]
[***]    [***]    [***]    [***]    [***]    Weather Shelter    [***]
[***]    [***]    [***]    [***]    [***]    Buildings changes    [***]
[***]    [***]    [***]    [***]    [***]    Add vehicle diesel fueling station    [***]
[***]    [***]    [***]    [***]    [***]    Notice of change: - MTSA MOF    [***]
[***]    [***]    [***]    [***]    [***]    Notice of change: F&G Analysis    [***]
[***]    [***]    [***]    [***]    [***]    KZJV to be Importer of Record for KZJV Material related to KZJV Work    [***]
[***]    [***]    [***]    [***]    [***]    Warm Flare KO Drum Electric Heater Removal    [***]
[***]    [***]    [***]    [***]    [***]    PTS Impoundment Basin Changes    [***]
[***]    [***]    [***]    [***]    [***]    Additional Filters.    [***]


Price:

The Parties have agreed to adjust the Target Price by the amount of [***] in respect of all of the items described in clause (1) above. This Change Order constitutes compensation in full, and final and complete satisfaction, for the adjustments to the Target Price related to the items described in clause (1) above.

 

Initial Target Price:    [***]   
Current Target Price:    [***]   
Value of Change Order:    [***]   
Adjusted Target Price as a result of this Change Order:    [***]   

Deliverable Schedule:

This Change Order shall have no impact on the Project Schedule or Applicable Deadlines.

This Change Order is not valid, except as otherwise provided in the Agreement, until fully executed by Contractor and Owner.

[Signatures on the following page.]


IN WITNESS WHEREOF, the Parties have caused this Change Order to be executed by their duly authorized representatives as of the date and year first above written.

 

Venture Global Plaquemines LNG, LLC

    KZJV LLC
By:  

/s/ Keith Larson

    By:  

/s/ Pamela C. Roche

Name:   Keith Larson     Name:   Pamela C. Roche
Title:   Secretary     Title:   VP Project Management
      By:  

/s/ Thomas Augustine

      Name:   Thomas Augustine
      Title:   Deputy Project Director

Exhibit 10.13

Execution Version

AMENDMENT NO. 3 TO

SECOND AMENDED AND RESTATED

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

THIS AMENDMENT NO. 3 TO SECOND AMENDED AND RESTATED ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Amendment”), entered into effective, except as otherwise noted, as of September 26, 2023 (the “Effective Date”), is entered into by and between VENTURE GLOBAL PLAQUEMINES LNG, LLC, a Delaware limited liability company (“Owner”), and KZJV LLC, a Texas limited liability company (“Contractor”).

WITNESSETH

WHEREAS, Owner and Contractor are parties to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement dated as of January 7, 2022, as amended by Amendment No. 1 dated as of October 11, 2022, and Amendment No. 2 as of February 1, 2023 (the “Agreement”); and

WHEREAS, pursuant to Section 41.8 of the Agreement, the Parties desire to amend the Agreement as set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants and provisions herein contained, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby covenant and agree as follows:

1. Defined Terms. Capitalized terms not defined in this Amendment shall have the meaning given to such terms in the Agreement.

2. Amendments. Effective as of the Effective Date, the Agreement is hereby amended as follows:

(i) The definition of “Contractor’s Margin” in Article 1 of the Agreement revised by Amendment No. 1, and inadvertently deleted in Amendment 2 is re-instated and remains effective from the Amendment No. 1 Effective Date forward.

Contractor’s Margin” means Contractor’s profit margin for the Work which, in respect of each Margin Milestone shall be calculated as follows:

CM = Base Target Price x MP x FP

Where:

CM = Contractor’s Margin for the relevant Margin Milestone

MP = the Margin Percentage, as adjusted pursuant to Section 8.2.

FP = the fixed milestone percentage for the relevant Margin Milestone set forth in Appendix 1 of Exhibit D.

 

1


Execution Version

(ii) Exhibit C to the Agreement is deleted in its entirety and replaced with the document attached as Attachment A to this Amendment.

(iii) Exhibit F, Attachments F-15 and F-16 to the Agreement are deleted in their entirety and replaced with the forms attached as Attachment B to this Amendment.

(iv) Exhibit A, Attachment 2 (Applicable Codes and Standards) is hereby amended by appending a new Attachment 2 thereto in the form attached as Attachment C to this Amendment.

(v) Exhibit G (Training Requirements) is deleted in its entirety and replaced with the document attached as Attachment D to this Amendment.

(vi) Exhibit H (Schedule of Major Vendors) is deleted in its entirety and replaced with the document attached as Attachment E to this Amendment.

(vii) Exhibit K (Key Personnel) - is deleted in its entirety and replaced with the document attached as Attachment F to this Amendment.

(viii) Exhibit O (Schedule of Major Subcontractors) is deleted in its entirety and replaced with the document attached as Attachment G to this Amendment.

(ix) Exhibit Y Appendix Y-1 Figure 1 is deleted in its entirety and replaced with the figure set forth in the document attached as Attachment H to this Amendment.

3. Benefits. This Amendment shall inure to the benefit of and be binding upon the Parties and their respective successors and permitted assigns. Except with respect to the rights of successors and permitted assigns as provided in the Agreement, including any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders), nothing express or implied in this Amendment is intended to confer upon any person, other than the Parties and their respective successors and assigns, any rights, remedies, obligations or liabilities under or by reason of this Amendment.

4. Effect of Amendment. Except as specifically set forth herein, the Agreement, as amended by this Amendment, remains in full force and effect in accordance with its terms.

5. Governing Law. This Amendment shall in all respects be governed by, and construed in accordance with the laws of the State of New York without regard to principles of conflicts of laws.

6. Counterparts. This Amendment may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute one and the same instrument. A signed copy of this Amendment transmitted by facsimile or email shall be treated as an original and shall be binding against the Party whose signature appears on such copy.

[signatures appear on following page]

 

2


Execution Version

IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their duly authorized representatives as of the Effective Date.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC
By:   /s/ Keith Larson
Name:   Keith Larson
Title   Secretary

 

KZJV LLC
By:   /s/ Paul Fellows
Name:   Paul Fellows
Title   Manager

 

By:   /s/ Matt Key
Name:   Matt Key
Title   Manager

 

3


Execution Version

Attachment A

EXHIBIT C

CONTRACTOR RATES

[Omitted]

 

1


Execution Version

Attachment B

Exhibit F-15

FORM OF PAYMENT STATUS AFFIDAVIT

[Omitted]

 

2


Execution Version

Attachment C

Exhibit A

ATTACHMENT 2

APPLICABLE CODES AND STANDARDS

[Omitted]

 

6


Execution Version

Attachment D

EXHIBIT G

TRAINING REQUIREMENTS

[Omitted]

 

7


Execution Version

Attachment E

Exhibit H - Schedule of Major Vendors

[Omitted]

 

9


Execution Version

Attachment F

EXHIBIT K

LIST OF CONTRACTOR’S KEY PERSONNEL

[Omitted]

 

9


Execution Version

Attacment G

Exhibit O

SCHEDULE OF MAJOR SUBCONTRACTORS

[Omitted]

 

12

Exhibit 10.14

Execution Version

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

AMENDMENT NO. 4 TO

SECOND AMENDED AND RESTATED

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

THIS AMENDMENT NO. 4 TO SECOND AMENDED AND RESTATED ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Amendment”), entered into effective as of September 26, 2023 (the “Effective Date”), is entered into by and between VENTURE GLOBAL PLAQUEMINES LNG, LLC, a Delaware limited liability company (“Owner”), and KZJV LLC, a Texas limited liability company (“Contractor”).

WITNESSETH

WHEREAS, Owner and Contractor are parties to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement dated as of January 7, 2022, as amended by Amendment No. 1 dated as of October 11, 2022, Amendment No. 2 dated as of February 1, 2023 and Amendment No. 3 dated as of September 26, 2023 (the “Agreement”); and

WHEREAS, the Parties are aware of the current Project Schedule progress, and Owner wishes to implement the incentive program set forth herein; and

WHEREAS, pursuant to Section 41.8 of the Agreement, the Parties desire to amend the Agreement as set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants and provisions herein contained, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby covenant and agree as follows:

1. Defined Terms. Capitalized terms not defined in this Amendment shall have the meaning given to such terms in the Agreement.

2. Amendments. Effective as of the Effective Date, the Agreement is hereby amended as follows:

(i) Article 1 of the Agreement is hereby amended to insert the following new defined terms in alphabetical order:

““Certificate of Incentive Performance Milestone Achievement” means the certificate, in substantially the form set forth as Exhibit F-19, to be provided by Contractor confirming in writing that the particular Incentive Performance Milestone has been achieved and explaining how it was achieved.

Eligible Personnel” means Contractor’s or its Affiliate’s personnel assigned to a eligible position identified on Exhibit AA who: (i) is engaged in the performance of the Work at the Job Site on a full-time basis for a period of at least six (6) consecutive months prior to the completion of the relevant Incentive Performance Milestone; (ii) has an Owner-approved PAAF and remains working on the Job Site through the applicable demobilization date, as mutually agreed upon by Owner and Contractor (such agreement to demobilize shall not be unreasonably withheld by Owner); (iii) is employed in good standing (as determined by Contractor) as of the date on which the relevant Incentive Payment is to be paid; (iv) is identified on Contractor’s performance milestone incentive list, as approved by Owner and updated by Contractor on a monthly basis and (v) is not part of part of Contractor’s commissioning staff.

 

1


Incentive Level means, with respect to any Eligible Personnel, the numeric incentive level identified opposite such Eligible Personnel’s position on Exhibit AA.

Incentive Payment means, with respect to any Eligible Personnel, the amount payable by Owner on the basis of such Eligible Personnel’s Incentive Level upon the completion of an Incentive Performance Milestone.

Incentive Performance Milestone means a milestone identified as an Incentive Performance Milestone on Exhibit AA.

Incentive Performance Milestone Deadline means, with respect to any Incentive Performance Milestone, the date identified on Exhibit AA as the incentive performance milestone deadline for such Incentive Performance Milestone.”

(ii) Article 16 of the Agreement is hereby amended by inserting the following new Section 16.4 immediately following Section 16.3:

“16.4 PERFORMANCE INCENTIVES

16.4.1 In consideration for Contractor’s safe and timely completion of the Work, Owner will, subject to Section 16.4.5, pay to Contractor, not later than [***] following the date of achievement of an Incentive Performance Milestone and Request for Payment, an amount in respect of such Incentive Performance Milestone equal to the sum of one (1) Incentive Payment for each and every Eligible Personnel; provided that Contractor has achieved such Incentive Performance Milestone on or prior to the applicable Incentive Performance Milestone Deadline. Contractor shall not be entitled to payment in respect of any Incentive Payment unless and until the achievement of the relevant Incentive Performance Milestone is confirmed by a Certificate of Incentive Performance Milestone Achievement to be provided by Contractor together with the relevant Request for Payment.

 

2


16.4.2 If Contractor achieves an Incentive Performance Milestone after the relevant Incentive Performance Milestone Deadline, no Incentive Payment shall be due and payable by Owner in respect of such Incentive Performance Milestone. For the avoidance of doubt and solely for the purposes set forth herein, the Incentive Performance Milestone Deadlines defined herein are not subject to adjustment for any reason, including Owner Caused Delay and Force Majeure.

16.4.3 Contractor shall invoice Owner for any Incentive Payment due and payable hereunder by submitting to Owner, together with the applicable Request for Payment, [***], and a certificate by an authorized representative of Contractor that certifies the invoice is in compliance with this Section 16.4. No Incentive Payment due and payable under this Agreement shall be considered a “Direct Cost” or included in the calculation of Contractor’s G&A or Contractor’s Margin, nor shall such amounts affect or modify the Target Price or the calculation of Total Costs or Total Cost Exclusions.

16.4.4 If an Eligible Personnel in respect of whom an Incentive Payment has been made by Owner ceases to be an Eligible Personnel prior to the approved maturity date for such Eligible Personnel, all Incentive Payments paid in respect of such Eligible Personnel shall be credited to Owner in Contractor’s next following Request for Payment.

16.4.5 Owner shall be permitted, without cause and for any reason, to cancel all future, unearned Incentive Payments and Incentive Performance Milestones at any time without liability to Owner by written notice to Contractor. In such event, Owner shall pay to Contractor any accrued and unpaid Incentive Payments outstanding at the time of such cancellation.

16.4.6 Contractor shall have sole responsibility for the disbursement of Incentive Payments to its Eligible Personnel and for the payment of all applicable Taxes in connection therewith. Contractor shall have sole responsibility for ensuring that the Incentive Payments are disbursed in accordance with all applicable labor and employment laws and regulations, and agrees to release, indemnify, defend and hold harmless each Owner Indemnitee from and against any and all Losses, of whatsoever kind or nature, which may directly or indirectly arise or result from Contractor’s failure to adhere to the requirements herein. Nothing in this Section 16.4 amends or modifies any obligation of Contractor under Article 24.”

(iii) Exhibit F to the Agreement is hereby amended by inserting a new Exhibit F-19 immediately following Exhibit F-18, in the form attached as Attachment A to this Amendment.

 

3


(iv) A new Exhibit AA to the Agreement is attached as Attachment B to this Amendment.

3. Benefits. This Amendment shall inure to the benefit of and be binding upon the Parties and their respective successors and permitted assigns. Except with respect to the rights of successors and permitted assigns as provided in the Agreement, including any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders), nothing express or implied in this Amendment is intended to confer upon any person, other than the Parties and their respective successors and assigns, any rights, remedies, obligations or liabilities under or by reason of this Amendment.

4. Effect of Amendment. Except as specifically set forth herein, the Agreement, as amended by this Amendment, remains in full force and effect in accordance with its terms.

5. Governing Law. This Amendment shall in all respects be governed by, and construed in accordance with the laws of the State of New York without regard to principles of conflicts of laws.

6. Counterparts. This Amendment may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute one and the same instrument. A signed copy of this Amendment transmitted by facsimile or email shall be treated as an original and shall be binding against the Party whose signature appears on such copy.

[signatures appear on following page]

 

4


IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their duly authorized representatives as of the Effective Date.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC
By:   /s/ Keith Larson
Name:   Keith Larson
Title:   Secretary

 

KZJV LLC
By:   /s/ Paul Fellows
Name:   Paul Fellows
Title:  

Manager

 

By:   /s/ Matt Key
Name:   Matt Key
Title:   Manager

 

5


Attachment A

EXHIBIT F-19

FORM OF CERTIFICATE OF INCENTIVE PERFORMANCE MILESTONE ACHIEVEMENT

[Omitted]

 

1


Attachment B

EXHIBIT AA

INCENTIVE PERFORMANCE MILESTONES, INCENTIVE LEVELS AND ELIGIBLE POSITIONS

[Omitted]

 

1

Exhibit 10.15

AMENDMENT NO. 5 TO

SECOND AMENDED AND RESTATED

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

THIS AMENDMENT NO. 5 TO SECOND AMENDED AND RESTATED ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Amendment”), entered into effective as of January 19, 2024 (the “Effective Date”), is entered into by and between VENTURE GLOBAL PLAQUEMINES LNG, LLC, a Delaware limited liability company (“Owner”), and KZJV LLC, a Texas limited liability company (“Contractor”).

W I T N E S S E T H

WHEREAS, Owner and Contractor are parties to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement dated as of January 7, 2022, as amended by Amendment No. 1 dated as of October 11, 2022, Amendment No. 2 dated as of February 1, 2023, Amendment No. 3 dated as of September 26, 2023 and Amendment No. 4 dated as of September 26, 2023 (the “Agreement”); and

WHEREAS, pursuant to Section 41.8 of the Agreement, the Parties desire to amend the Agreement as set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants and provisions herein contained, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby covenant and agree as follows:

1. Defined Terms. Capitalized terms not defined in this Amendment shall have the meaning given to such terms in the Agreement.

2. Amendments. Effective as of the Effective Date, the Agreement is hereby amended as follows:

(i) Article 1 of the Agreement is hereby amended to delete the defined term “Cost Overrun” in its entirety and to insert the following new defined term in its place:

““Cost Overrun” means an amount equal to the amount by which the Total Costs forecasted by Contractor to be incurred as of a given date exceed the Target Price.”

(ii) Article 1 of the Agreement is hereby amended to insert the following new defined term in alphabetical order:

““Margin Refund” has the meaning set forth in Section 8.2.2.”

 

1


 

(iii) Section 6.3.12 of the Agreement is hereby deleted in its entirety and the following new Section 6.3.12 shall be inserted in its place:

“6.3.12 The Parties acknowledge that the amount of Contractor’s Margin payable by Owner in respect of each Margin Milestone is calculated based on a percentage of the then applicable Base Target Price. The following methodology will be applied with respect to any (i) adjustment to the Base Target Price after the Effective Date, (ii) instance where the aggregate amount of Direct Costs (other than Tax Costs) and Agent for Contract Costs (other than Tax Costs) forecasted by Contractor in the performance of the Reimbursable Work exceeds the then applicable Base Target Price or (iii) early termination of this Agreement or forecast reconciliation as per clause (d) of this Section 6.3.12:

(a) Upon an increase to the Base Target Price, the amount payable for each Margin Milestone in respect of which Contractor’s Margin has previously been paid shall be automatically increased to reflect the applicable milestone percentage of the amount of the increase to the Base Target Price, and the positive difference between such increased amount payable and the amount previously paid shall be invoiced by Contractor to Owner in the next following Request for Payment; provided, however, that any portion of the increase to the Base Target Price that has previously been invoiced to Owner and paid in accordance with clause (c) of this Section 6.3.12 shall be excluded from the application of this clause (a).

(b) Upon a decrease to the Base Target Price, the amount payable for each Margin Milestone in respect of which Contractor’s Margin has previously been paid shall be automatically decreased to reflect the applicable milestone percentage of the amount of the decrease to the Base Target Price, and the positive difference between the amount previously paid and such decreased amount payable shall be applied as a credit to Owner in the next following Request for Payment.

(c) If at any time the aggregate amount of Direct Costs and Agent for Contract Costs forecasted by Contractor in the performance of Reimbursable Work exceeds the then applicable Base Target Price, payments of Contractor’s Margin for all Margin Milestones shall be recalculated by applying such aggregate amount in place of the Base Target Price in the definition of “Contractor’s Margin”, and the difference resulting from such recalculation shall, with respect to each Margin Milestone in respect of which Contractor’s Margin has previously been paid, be invoiced by Contractor to Owner in the next following Request for Payment; provided, however, that the Contractor’s Margin shall not be adjusted pursuant to this clause (c) more than once every ninety (90) days.

(d) If this Agreement is terminated pursuant to and in accordance with Article 31 or the final aggregate amount of Direct Costs and Agent for Contract Costs incurred are less than the final amount forecasted by Contractor pursuant to clause (c) above, the amount of Contractor’s Margin

 

2


 

owed to Contractor upon such termination shall be calculated on the basis of all Direct Costs (other than Tax Costs) and Agent for Contract Costs (other than Tax Costs) incurred in the performance of Reimbursable Work prior to the date of such termination rather than the Appendix 1 of Exhibit D Margin Milestone payment schedule. If the amount of Contractor’s Margin calculated pursuant to the preceding sentence is greater or less than the aggregate amount of Contractor’s Margin paid to Contractor prior to the date of such termination, the difference shall be paid to Contractor or Owner, respectively.”

(iv) Section 8.2.2 of the Agreement is hereby amended to delete the third sentence thereof and to insert the following new sentence in its place:

“In such event, without prejudice to Section 41.7, Owner may deduct from amounts owed to Contractor hereunder an amount equal to the positive difference between the amount of the Contractor’s Margin previously billed to Owner pursuant to Section 6.3 calculated using the previously applicable Margin Percentage less the amount of the Contractor’s Margin as recalculated applying the reduced Margin Percentage to Margin Milestones previously billed to Owner based on Contractor’s forecast (such positive difference, the Margin Refund”), by deducting an amount equal to one-third of the Margin Refund from each of the next three Requests for Payment submitted by Contractor pursuant to Section 6.3.”

3. Benefits. This Amendment shall inure to the benefit of and be binding upon the Parties and their respective successors and permitted assigns. Except with respect to the rights of successors and permitted assigns as provided in the Agreement, including any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders), nothing express or implied in this Amendment is intended to confer upon any person, other than the Parties and their respective successors and assigns, any rights, remedies, obligations or liabilities under or by reason of this Amendment. 

4. Effect of Amendment. Except as specifically set forth herein, the Agreement, as amended by this Amendment, remains in full force and effect in accordance with its terms.

5. Governing Law. This Amendment shall in all respects be governed by, and construed in accordance with the laws of the State of New York without regard to principles of conflicts of laws.

6. Counterparts. This Amendment may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute one and the same instrument. A signed copy of this Amendment transmitted by facsimile or email shall be treated as an original and shall be binding against the Party whose signature appears on such copy.

[signatures appear on following page]

 

3


 

IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their duly authorized representatives as of the Effective Date.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC
By:  

/s/ Keith Larson

Name:   Keith Larson
Title:   Secretary
KZJV LLC
By:  

/s/ Paul Fellows

Name:   Paul Fellows
Title:   Manager
By:  

/s/ Matt Key

Name:   Matt Key
Title:   Manager

 

4

Exhibit 10.16

Execution Version

AMENDMENT NO. 6 TO

SECOND AMENDED AND RESTATED

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

THIS AMENDMENT NO. 6 TO THE SECOND AMENDED AND RESTATED ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Amendment”), entered into and effective, as of July 2, 2024 (the “Effective Date”), by and between VENTURE GLOBAL PLAQUEMINES LNG, LLC, a Delaware limited liability company (“Owner”) and KZJV LLC, a Texas limited liability company (“Contractor”).

W I T N E S S E T H

WHEREAS, Owner and Contractor are parties to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement dated as of January 7, 2022, as amended by Amendment No. 1 dated as of October 11, 2022, Amendment No. 2 as of February 1, 2023, Amendment No. 3 as of September 26, 2023, Amendment No. 4 as of September 26, 2023, and Amendment No. 5 dated January 19, 2024 (the “Agreement”); and

WHEREAS, pursuant to Section 41.8 of the Agreement, the Parties desire to amend the Agreement as set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants and provisions herein contained, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby covenant and agree as follows:

1. Defined Terms. Capitalized terms not defined in this Amendment shall have the meaning given to such terms in the Agreement.

2. Amendments. Effective as of the November 6, 2023, the Agreement is hereby amended as follows:

(i) Exhibit C-5 to the Agreement is deleted in its entirety and replaced with the document included herein as Attachment A to this Amendment.

(ii) Exhibit K to the Agreement is deleted in its entirety and replaced with the document included herein as Attachment B to this Amendment.

3. Benefits. This Amendment shall inure to the benefit of and be binding upon the Parties and their respective successors and permitted assigns. Except with respect to the rights of successors and permitted assigns as provided in the Agreement, including any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders), nothing express or implied in this Amendment is intended to confer upon any person, other than the Parties and their respective successors and assigns, any rights, remedies, obligations or liabilities under or by reason of this Amendment.

 

1


 

4. Effect of Amendment. Except as specifically set forth herein, the Agreement, as amended by this Amendment, remains in full force and effect in accordance with its terms.

5. Governing Law. This Amendment shall in all respects be governed by, and construed in accordance with the laws of the State of New York without regard to principles of conflicts of laws.

6. Counterparts. This Amendment may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute one and the same instrument. A signed copy of this Amendment transmitted by facsimile or email shall be treated as an original and shall be binding against the Party whose signature appears on such copy.

[signatures appear on following page]

 

2


 

IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their duly authorized representatives as of the Effective Date.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC
By: /s/ Keith Larson             
Name: Keith Larson
Title: Secretary
KZJV LLC
By: /s/ Paul Fellows             
Name: Paul Fellows
Title: Manager
By: /s/ Matt Key               
Name: Matt Key
Title: Manager

 

3


Execution Version

 

Attachment A

Revised Exhibit C-5

[Omitted]


Execution Version

 

Attachment B

Revised Exhibit K

EXHIBIT K

[Omitted]

Exhibit 10.17

Execution Version

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

between

VENTURE GLOBAL PLAQUEMINES LNG, LLC

as Owner

and

KZJV LLC

as Contractor

Dated as of January 10, 2023

RELATING TO PHASE 2 OF THE LNG EXPORT AND LIQUEFACTION FACILITY

TO BE LOCATED ON THE WEST BANK OF THE MISSISSIPPI RIVER, NEAR

RIVER MILE MARKER 55, IN PLAQUEMINES PARISH, LOUISIANA

 


 

TABLE OF CONTENTS

 

           Page  

1.

 

DEFINITIONS

     2  

2.

 

AGREEMENT; EXHIBITS; CONFLICTS

     24  
  2.1   LANGUAGE OF AGREEMENT      24  
  2.2   PRECEDENCE OF AGREEMENT      24  
  2.3   INTERPRETATION      25  
  2.4   NEGOTIATION AND DOCUMENTATION OF THIS AGREEMENT      26  

3.

 

GENERAL PROVISIONS

     26  
  3.1   WORK TO BE PERFORMED      26  
  3.2   GENERAL OVERSIGHT AND ACCESS      27  
  3.3   JOB SITE CONDITIONS      28  
  3.4   OWNER NOT RESPONSIBLE FOR ACTS OF CONTRACTOR; CONTRACTOR NOT RESPONSIBLE FOR OWNER SCOPE OF WORK      28  
  3.5   EFFECT OF AND TIME FOR OWNER REVIEW OF DOCUMENTS      29  
  3.6   CLAIMS UPON FAILURE OF MATERIAL      29  
  3.7   RESPONSIBILITIES OF OWNER      30  
  3.8   RESPONSIBILITIES OF CONTRACTOR      31  
  3.9   SPARE PARTS      40  
  3.10   PROCUREMENT      40  

4.

 

COMMENCEMENT OF THE WORK

     41  
  4.1   NOTICE TO PROCEED      41  
  4.2   LIMITED NOTICES TO PROCEED      42  

5.

 

PERSONNEL AND QUALIFICATIONS

     42  
  5.1   GENERAL      42  
  5.2   KEY PERSONNEL      43  

6.

 

PRICE AND PAYMENT

     43  
  6.1   TARGET PRICE      43  
  6.2   NOT USED      44  
  6.3   PAYMENT      44  
  6.4   ENCUMBRANCES      47  
  6.5   DEFICIENT REQUESTS FOR PAYMENT      47  
  6.6   OWNER PAYMENT OBLIGATIONS      48  

 

i


 

  6.7    FINAL PAYMENT      48  
  6.8    OWNER’S RIGHT TO WITHHOLD PAYMENT      48  
  6.9    RELEASE OF LIABILITY      50  

7.

 

SCHEDULE BONUSES

     50  
  7.1    INTERIM MILESTONE BONUSES      50  
  7.2    PRIMARY MILESTONE BONUSES      50  
  7.3    SUPER PRIMARY MILESTONE BONUSES      51  
  7.4    LIMITATIONS      52  

8.

 

COST OVERRUN; COST SAVINGS

     53  
  8.1    TOTAL COSTS      53  
  8.2    COST OVERRUN      53  
  8.3    COST SAVINGS      54  

9.

 

PERFORMANCE SECURITY

     55  
  9.1    TYPES OF PERFORMANCE SECURITY      55  
  9.2    PERFORMANCE AND PAYMENT BONDS      55  
  9.3    CONTRACTOR GUARANTEES      56  

10.

 

QUALITY CONTROL AND INSPECTION

     57  
  10.1    QUALITY MANAGEMENT PLAN      57  
  10.2    DEFECTS AND DEFICIENCIES      57  
  10.3    INSPECTION RIGHTS      58  
  10.4    THIRD PARTY INSPECTION      58  
  10.5    EFFECT OF WAIVER OF INSPECTION RIGHTS      59  

11.

 

HEALTH, SAFETY, SECURITY AND ENVIRONMENT

     59  
  11.1    COMPLIANCE      59  
  11.2    HSSE PROGRAM      59  
  11.3    SAFEGUARDS      60  
  11.4    HSSE INCIDENTS      60  

12.

 

CHANGES IN THE WORK

     61  
  12.1    GENERAL      61  
  12.2    CHANGE ORDER PROCESS      63  
  12.3    DISPUTED CHANGES      64  
  12.4    CHANGES DUE TO UNKNOWN SUBSURFACE CONDITIONS      64  
  12.5    INFORMATION REQUESTS      65  

 

ii


 

13.

 

PROJECT SCHEDULE AND MONTHLY PROGRESS REPORTS

     65  
  13.1    GENERAL      65  
  13.2    PROJECT SCHEDULE      65  
  13.3    MONTHLY PROGRESS REPORTS      66  

14.

 

TRAINING

     66  

15.

 

TESTING

     67  
  15.1    FACTORY TESTS      67  
  15.2    DEMONSTRATION TESTING      67  
  15.3    PERFORMANCE TESTING      67  
  15.4    CORRECTION OF PERFORMANCE DEFECTS OR DEFICIENCIES      69  

16.

 

TIME FOR PERFORMANCE AND SCHEDULE

     70  
  16.1    TIME FOR COMPLETION      70  
  16.2    FAILURE TO MITIGATE      71  
  16.3    RECOVERY AND ACCELERATION OF WORK      71  

17.

 

SUSPENSION OR REJECTION OF THE WORK

     72  
  17.1    GENERAL      72  
  17.2    COMPENSATION TO CONTRACTOR FOR SUSPENSION      72  
  17.3    REJECTION OF WORK      73  
  17.4    CORRECTION OF WORK OR MATERIAL      73  
  17.5    FAILURE TO CORRECT MATERIAL      73  
  17.6    OTHER MATERIAL OR WORK DAMAGED      74  

18.

 

LNG PRODUCTION SYSTEM COMPLETION

     74  
  18.1    LNG PRODUCTION SYSTEM MECHANICAL COMPLETION      74  
  18.2    LNG PRODUCTION SYSTEM RFSU      75  
  18.3    LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION      76  

19.

 

FACILITY COMPLETION

     76  
  19.1    FACILITY MECHANICAL COMPLETION      76  
  19.2    FACILITY SUBSTANTIAL COMPLETION      77  
  19.3    READY FOR SHIP LOADING      78  
  19.4    FINAL COMPLETION      79  
  19.5    PUNCH LIST ITEMS      80  

20.

 

WARRANTY FOR DEFECTS

     80  
  20.1    IN GENERAL      80  

 

iii


 

  20.2    SPECIFIC WARRANTIES      81  
  20.3    NOTICE OF DEFECTS OR DEFICIENCIES      82  
  20.4    EXTENSION OF WARRANTY PERIOD      82  
  20.5    FAILURE TO REMEDY DEFECTS      83  
  20.6    REMOVAL AND OWNERSHIP OF DEFECTIVE WORK      83  
  20.7    FURTHER TESTS      83  
  20.8    RIGHT OF ACCESS      83  
  20.9    SUBCONTRACTOR AND AGENT FOR CONTRACTOR WARRANTIES      84  
  20.10    NO IMPLIED WARRANTIES      84  
  20.11    REPAIRS AND TESTING BY OWNER      84  
  20.12    SURVIVAL OF WARRANTIES      85  

21.

 

LIABILITY

     85  
  21.1    TOTAL LIABILITY CAP      85  
  21.2    NO CONSEQUENTIAL DAMAGES      86  
  21.3    JOINT AND SEVERAL LIABILITY      86  

22.

 

PERFORMANCE TESTS; LIQUIDATED DAMAGES

     86  
  22.1    PERFORMANCE TESTS      86  
  22.2    SCHEDULE DELAY LIQUIDATED DAMAGES FOR FAILURE TO ACHIEVE LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION OR FACILITY SUBSTANTIAL BY AN APPLICABLE DEADLINE      86  
  22.3    LIQUIDATED DAMAGES CAP      89  
  22.4    PAYMENT      89  
  22.5    LIQUIDATED DAMAGES REASONABLE      89  
  22.6    EFFECT ON OTHER PROVISIONS      90  

23.

 

SUBCONTRACTORS

     90  
  23.2    CONTRACTOR RESPONSIBLE FOR WORK      91  
  23.3    ASSIGNMENT      91  
  23.4    AGENT FOR CONTRACTS WORK      92  

24.

 

LABOR RELATIONS

     92  
  24.1    GENERAL MANAGEMENT OF EMPLOYEES      92  
  24.2    WAGES AND CONDITIONS      92  
  24.3    VIOLATIONS      93  
  24.4    DISPUTES      93  
  24.5    STATUTORY EMPLOYER      93  
  24.6    LOCAL LABOR      93  
  24.7    COMMUNITY IMPACTS      94  

 

iv


 

25.

 

TITLE AND RISK OF LOSS

     94  
  25.1    TRANSFER OF TITLE      94  
  25.2    RISK OF LOSS      94  
  25.3    PROTECTION OF OWNER      95  

26.

 

INSURANCE

     95  
  26.1    IN GENERAL      95  
  26.2    POLICIES TO BE OBTAINED BY CONTRACTOR      96  
  26.3    POLICIES TO BE OBTAINED BY OWNER      100  

27.

 

CONFIDENTIAL TREATMENT OF PROPRIETARY INFORMATION; RELIANCE ON INFORMATION

     102  
  27.1    CONFIDENTIAL TREATMENT      102  
  27.2    RELIANCE ON INFORMATION      104  

28.

 

REPRESENTATIONS AND WARRANTIES

     104  
  28.1    OWNER REPRESENTATIONS AND WARRANTIES      104  
  28.2    CONTRACTOR REPRESENTATIONS AND WARRANTIES      105  

29.

 

INTELLECTUAL PROPERTY AND LICENSES

     107  
  29.1    OWNERSHIP      107  
  29.2    LICENSES      107  
  29.3    DATA      108  

30.

 

INDEMNIFICATION

     108  
  30.1    CONTRACTOR INDEMNITY      108  
  30.2    OWNER INDEMNITY      110  
  30.3    ACTIONS BY EMPLOYEES      111  
  30.4    NOTICE AND DEFENSE      111  
  30.5    REMEDIES NOT EXCLUSIVE      112  
  30.6    TAX EFFECT OF INDEMNIFICATION      112  

31.

 

EVENTS OF DEFAULT; REMEDIES

     112  
  31.1    CONTRACTOR EVENTS OF DEFAULT      112  
  31.2    REMEDIES      114  
  31.3    DAMAGES      115  
  31.4    OWNER REMEDIES      115  
  31.5    OWNER DEFAULT      116  
  31.6    OBLIGATIONS UPON TERMINATION      116  

 

v


 

32.

 

TERMINATION FOR CONVENIENCE

     117  
  32.1    GENERAL      117  
 

32.2

  

CLAIMS FOR PAYMENT FOLLOWING TERMINATION FOR CONVENIENCE

     118  

33.

 

FORCE MAJEURE

     118  
  33.1    EXTENSION OF TIME FOR FORCE MAJEURE EVENT      118  
 

33.2

  

CONTRACTOR’S RESPONSIBILITY

     118  
 

33.3

  

CONTINUING RESPONSIBILITY OF CONTRACTOR

     119  
 

33.4

  

PERFORMANCE NOT EXCUSED

     119  

34.

 

DUTIES AND TAXES

     119  
  34.1    ALLOCATION OF RESPONSIBILITIES      119  
 

34.2

  

LOUISIANA TAX AND INCENTIVES PROVISIONS

     120  

35.

 

BINDING AGREEMENT; ASSIGNMENT

     120  
  35.1    BY OWNER      120  
 

35.2

  

BY CONTRACTOR

     120  

36.

 

DISPUTES

     121  
  36.1    DISPUTE RESOLUTION      121  
 

36.2

  

CONTINUATION OF WORK DURING DISPUTE

     122  

37.

 

INDEPENDENT CONTRACTOR

     123  
  37.1    GENERAL      123  
 

37.2

  

EMPLOYEES

     123  
 

37.3

  

RESPONSIBILITY FOR SUBCONTRACTORS, ETC

     123  

38.

 

NOTICES AND COMMUNICATIONS

     123  
  38.1    REQUIREMENTS      123  
 

38.2

  

EFFECTIVE TIME

     124  
 

38.3

  

TECHNICAL COMMUNICATIONS

     124  

39.

 

FINANCING MATTERS

     125  

40.

 

COMPLIANCE WITH LAWS

     125  
  40.1    ANTI-CORRUPTION      125  
 

40.2

  

RECORDS

     126  
 

40.3

  

EXPORT CONTROLS

     127  
 

40.4

  

SUBCONTRACTORS; INDEMNIFICATION

     127  

 

vi


 

41.

 

MISCELLANEOUS

     128  
  41.1    FURTHER ASSURANCES AND EXPENSES      128  
  41.2    RECORD RETENTION      128  
  41.3    NO WAIVER      128  
  41.4    SEVERABILITY      128  
  41.5    BINDING ON SUCCESSORS      128  
  41.6    GOVERNING LAW      129  
  41.7    SET-OFF      129  
  41.8    AMENDMENT      129  
  41.9    HEADINGS FOR CONVENIENCE ONLY      129  
  41.10    NONDISCRIMINATION      130  
  41.11    COUNTERPART EXECUTION      130  
  41.12    THIRD-PARTY BENEFICIARIES      130  
  41.13    SURVIVAL OF OBLIGATIONS      130  
  41.14    ENTIRE AGREEMENT      130  
  41.15    RELATIONSHIP      131  
  41.16    LIMITED RECOURSE      131  

 

 

vii


 

Exhibits:         
Exhibit A    Scope of Work; Applicable Codes and Standards
Exhibit B    Compensation   
   Exhibit    B-1    Direct Costs and Non-Reimbursable Costs
   Exhibit    B-2    Target Price Components
   Exhibit    B-3    Cover Costs Examples
   Exhibit    B-4    Payment Procedures
Exhibit C    Contractor Rates
Exhibit D    Schedule Milestones
Exhibit E    Project Schedule
Exhibit F    Contract Forms
   Exhibit    F-1    Form of Contractor Certificate for Partial Waiver of Liens
   Exhibit    F-2    Form of Subcontractor Certificate for Partial Waiver of Liens
   Exhibit    F-3    Form of Contractor Certificate for Final Waiver of Liens
   Exhibit    F-4    Form of Subcontractor Certificate for Final Waiver of Liens
   Exhibit    F-5    Form of Consent and Agreement
   Exhibit    F-6    Forms of Contractor Guarantee
   Exhibit    F-7    Form of Request for Payment
   Exhibit    F-8    Form of Limited Notice to Proceed
   Exhibit    F-9A    Form of Performance Bond
   Exhibit    F-9B    Form of Payment Bond
   Exhibit    F-10    Form of Change Order
   Exhibit    F-11    Form of LNG Production System Mechanical Completion Certificate
   Exhibit    F-12    Form of LNG Production System RFSU Certificate
   Exhibit    F-13    Form of Notice to Proceed
   Exhibit    F-14    Form of Title Insurance Indemnity Undertaking
   Exhibit    F-15    Form of Payment Status Affidavit (Contractor)
   Exhibit    F-16    Form of Subcontractor’s Payment Status Affidavit
   Exhibit    F-17    Form of Certificate of Achievement
   Exhibit    F-18    Form of Certificate of Schedule Milestone Achievement
Exhibit G    Training Requirements
Exhibit H    Schedule of Major Vendors
Exhibit I    Progress Reporting and Progress Meetings
Exhibit J    Document Control and Information Management
Exhibit K    List of Contractor’s Key Personnel
Exhibit L    Permits, Licenses and Government Approvals
Exhibit M    Relied Upon Information
Exhibit N    Owner Supplied Information
Exhibit O    Schedule of Major Subcontractors
Exhibit P    Mechanical Completion, Commissioning, Start-up and Substantial Completion
Exhibit Q    Owner Personnel
Exhibit R    Demonstration Tests and Performance Tests
Exhibit S    LNG Production System Handover Packages
Exhibit T    Requirements for Simultaneous Operation

 

1


 

Exhibit U    Health, Safety, Security and Environment Requirements
Exhibit V    First Fills and Catalysts
Exhibit W    [Reserved]
Exhibit Y    Coordination Procedure

 

2


 

THIS ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Agreement”) is made and entered into as of January 10, 2023 (the “Effective Date”) by and between VENTURE GLOBAL PLAQUEMINES LNG, LLC (“Owner”), a limited liability company duly organized and validly existing under the laws of the State of Delaware domiciled in and with its principal place of business located at 1001 19th Street North, Suite 1500, Arlington, VA 22209, and KZJV LLC, a limited liability company duly organized and validly existing under the laws of the State of Texas with its principal place of business at Corporation Trust Center, 1999 Bryan Street, Suite 900, Dallas, Texas 75201 (the “Contractor”).

W I T N E S E T H

WHEREAS, Owner is developing and intends to own and operate natural gas liquefaction facilities, including two phases, an export terminal and LNG storage facilities located on the west bank of the Mississippi River, near river mile marker 55, in Plaquemines Parish, Louisiana, all as more fully described herein and the Exhibits hereto;

WHEREAS, Owner desires to engage Contractor to perform certain design, engineering, procurement, and construction-related services in respect of the second phase, with a nameplate capacity of six decimal seven (6.7) million metric tonnes per annum of LNG (“Phase 2”), all as more fully described herein and in the Exhibits hereto;

WHEREAS, Contractor has (a) been provided and reviewed the conceptual drawings, the Owner Contracts and the other information relating to the Facility (as hereinafter defined) and all other documents relating to the Facility which Contractor and Owner have deemed necessary in connection with this Agreement, (b) inspected the Job Site (as hereinafter defined) and (c) performed or reviewed such other investigations, studies and analyses, which Contractor has determined to be necessary or prudent, in connection with the performance of the Work (as hereinafter defined);

WHEREAS, Contractor has represented that it is experienced and qualified in providing technical assistance, licensing, engineering, procurement, supply, construction management, construction, Pre-Commissioning (as hereinafter defined), Commissioning (as hereinafter defined) and testing services, and that it possesses the requisite expertise and resources to complete the Work to be performed by it;

WHEREAS, Contractor is performing certain construction management work in respect of site preparation activities pursuant to that certain Construction Management Agreement between Owner and Contractor dated as of September 7, 2022; and

WHEREAS, Contractor desires to complete the Work for Owner.

NOW, THEREFORE, in consideration of the sums to be paid to Contractor by Owner and of the covenants and agreements set forth herein, and for other good and valuable consideration, the receipt and adequacy of which is hereby acknowledged, the Parties hereto, intending to be legally bound, hereby agree as follows:


 

1.

DEFINITIONS.

For all purposes of this Agreement, except as otherwise expressly provided or unless the context otherwise requires, the following terms when capitalized herein (including the Exhibits) shall have the following meanings:

Abandonment of the Project” means Contractor’s refusal to perform substantially all home office activities and field construction operations in a manner that manifests the intent by Contractor of not completing the Work under this Agreement.

Affiliate” means, in relation to any Person, any other Person: (a) which directly or indirectly controls, or is controlled by, or is under common control with, such Person; or (b) which directly or indirectly beneficially owns or holds fifty percent (50%) or more of any class of voting stock or other equity interests of such Person, or (c) which has fifty percent (50%) or more of any class of voting stock or other equity interests that is directly or indirectly beneficially owned or held by such Person or (d) who either holds a general partnership interest in such Person or such Person holds a general partnership interest in the other Person. For purposes of this definition, the word “controls” means possession, directly or indirectly of the power to direct or cause the direction of the management or policies of a Person, whether through the ownership of voting securities or otherwise. For the avoidance of doubt, each Contractor Guarantor and each JV Member shall be deemed to be an Affiliate of Contractor under this Agreement.

Agent For Contractor” means any party to an Agent For Contract (other than Owner).

Agent For Contracts” means:

(a) the module fabrication and construction agreement(s) to be entered into between Owner and the relevant Agent For Contractor; and

(b) the module transportation agreement(s) to be entered into between Owner and the relevant Agent For Contractor.

Agent For Contracts Costs” means the amounts payable by Owner pursuant to and in accordance with the Agent For Contracts, excluding any amounts payable thereunder solely as a result of the Gross Negligence or Willful Misconduct of Senior Supervisory Personnel.

Agent For Contracts Work” means scope of work and other obligations set forth in the Agent For Contracts.

Agreement” has the meaning set forth in the introductory paragraph hereof, and shall be deemed to include all Exhibits to this Agreement, as each of the foregoing may be amended, modified and supplemented from time to time pursuant to the terms hereof.

Anti-Corruption Laws” has the meaning set forth in Section 40.1.2.

Applicable Codes and Standards” means those certain codes, requirements and standards applicable to the Facility, the Job Site, the Work, Contractor and/or any Subcontractors set forth in Exhibit A or in any applicable Law. In the event of an inconsistency or conflict between any of the Applicable Codes and Standards, the more stringent standard as contemplated therein shall govern Contractor’s performance under this Agreement.

 

2


 

Applicable Deadline” means (i) an LNG Production System Substantial Completion Deadline, the Facility Substantial Completion Deadline or the Final Completion Deadline, as applicable and (ii) solely for the purposes of the definitions of “Change Order”, “Critical Path” and (only to the extent contemplated in Appendix 2 of Exhibit D) “Owner Caused Delay” and Sections 12.1.8, 12.2.3, 12.5 and the second sentence of Section 16.1, a Completion Date associated with an Interim Milestone, a Primary Milestone or a Super Primary Milestone.

Base Target Price” means, as of any date, an amount equal to the sum of the Direct Costs (other than Tax Costs) and Agent for Contracts Costs (other than Tax Costs) components of the Target Price as of such date.

BH” means Baker Hughes Energy Services LLC, a Delaware limited liability company.

BH Testing Delay” has the meaning set forth within the definition of Owner Caused Delay.

Block” means a grouping of two (2) Liquefaction Trains in a Liquefaction Train System.

BSCFD” means Billion Standard Cubic Foot per Day.

Btu” or “British Thermal Unit” means the amount of heat required to raise the temperature of one avoirdupois pound of pure water from fifty-nine degrees (59°) Fahrenheit to sixty degrees (60°) Fahrenheit at a pressure of fourteen point six nine six (14.696) pounds per square inch absolute (psia).

Business Day” means any Day other than a Saturday, Sunday or a legal holiday in the State of New York (solely for the purpose of a payment obligation) or the State of Louisiana (with respect to all other obligations).

Carrollton Gage” means the gauge for measuring river level height of the Mississippi River located at Mississippi River mile 102.8 near New Orleans, Louisiana and commonly known as the “Carrollton gauge” or “Carrollton gage.”

Carrollton Gage Delay” means a Government Authority, including the United States Army Corps of Engineers or any applicable levee district, issues a navigation notice, denies, revokes, suspends or modifies a levee permit or a waiver application in respect to a levee permit, or formally takes any other action that has the effect of preventing or adversely impacting navigation, transport, loading, or unloading activity along an applicable stretch or stretches of the Mississippi River or construction activity within a prescribed distance from the Mississippi River levee or berm toe (e.g., subsurface work within 1,500 feet from the Mississippi River levee centerline), in each case due to the river stage exceeding eleven (+11.0) feet National Geodetic Vertical Datum (NGVD) at the Carrollton Gage, which directly and adversely impacts Contractor’s performance of Work at or near the Job Site.

 

3


 

Certificate of Achievement” means the certificate, in substantially the form set forth as Exhibit F-17, to be provided by Contractor confirming in writing that the particular Margin Milestone has been achieved and explaining how it was achieved.

Certificate of Schedule Milestone Achievement” means the certificate, in substantially the form set forth as Exhibit F-18, to be provided by Contractor confirming in writing that the particular Schedule Milestone has been achieved and explaining how it was achieved.

Change in Law” means (a) the enactment or issuance of any new Law or Permit applicable to the Facility, the Job Site and/or the Parties, (b) the amendment, alteration, modification or repeal of any existing Law or Permit applicable to the Facility (including any change to Facility noise or emissions limitations), the Job Site and/or the Parties, (c) any authoritative interpretation of any existing Law or Permit applicable to the Facility, the Job Site and/or the Parties, expressed in writing and issued by a Government Authority that is contrary to the existing official interpretation thereof, or (d) or any change in the Applicable Codes and Standards, which in the case of any of (a), (b), (c) or (d) above is enacted or adopted and is imposed and/or comes into effect after the Effective Date, and that must be complied with in order for the Facility to be constructed or operated lawfully; provided, however, that any change in any Law relating to income, capital, net worth or income withholding taxes shall not constitute a Change in Law for purposes hereof.

Change Order” means a document issued pursuant to Article 12 which authorizes, as applicable, a change in or to (a) the Work or the requirements set forth in Exhibit A, (b) the Target Price, (c) the Project Schedule, (d) the Critical Path, (e) an Applicable Deadline, (f) the (g) the Demonstration Tests; (h) Performance Tests (or protocol therefor) or (i) any right, liability or obligation of a Party or any other provision hereof, and is in the form attached hereto as Exhibit F-10.

Closed Cost Items” has the meaning set forth in Section 6.1.3.

Commissioning” means the commissioning activities performed by Contractor with respect to an LNG Production System after LNG Production System Mechanical Completion and Pre-Commissioning for such LNG Production System has occurred, as set forth in Exhibit P and Owner has accepted a Ready for Commissioning Certificate for such LNG Production System in accordance with Exhibit P. Commissioning includes all of the activities that are required to be completed in order to put the equipment and facilities into operation, to dynamically verify functionality of equipment and to ensure that systems, or facilities forming part of a system, are in accordance with specified requirements to bring that system into operation, including specialist flushing and cleaning, chemical and hydraulic cleaning, drying, oxygen freeing nitrogen and helium testing.

Completion Date” means, with respect to any Schedule Milestone, the date for completion of such Schedule Milestone set forth on Appendix 2 of Exhibit D.

Confidential Information” has the meaning set forth in Section 27.1.

Consent and Agreement” has the meaning set forth in Article 39.

 

4


 

Contractor” has the meaning set forth in the introductory paragraph hereof, and includes legal successors and permitted assigns as may be accepted by Owner, in writing, pursuant to the terms of this Agreement.

Contractor Confidential Information” has the meaning set forth in Section 27.1.2.

Contractor Guarantee” means the guarantees issued by each of the Contractor Guarantors in the form of Exhibit F-6.

Contractor Guarantor” means each of (i) KBR, Inc., a Delaware corporation and (ii) Zachry Holdings, Inc., a Delaware corporation, and “Contractor Guarantors” means both of them, collectively.

Contractor Indemnitee” means Contractor, the Contractor’s Representative, and all Affiliates, officers, directors, employees and agents thereof.

Contractor Intellectual Property” means all Intellectual Property that is (a) (i) owned by or licensed to Contractor or Contractor’s Affiliates as of the Effective Date or (ii) acquired during the term of this Agreement other than in connection with the Work, (b) disclosed by Contractor hereunder, and (c) necessary for, or used or held for use by Contractor and/or any Subcontractor in connection with the performance, completion, design, construction, installation, operation, maintenance, repair, replacement, modification, alteration or reconstruction of the Work.

Contractor’s G&A” means, in respect of each month that Contractor is eligible for reimbursement of Direct Costs or is managing Agent For Contractor Work, Contractor’s general and administrative expenses for such month, which shall be a fixed percentage during the term hereof and equal at all times to (i) [***] of the sum of the amount of Direct Costs (other than Tax Costs) that are reimbursable to Contractor and the Agent For Contracts Costs (other than Tax Costs) in respect of such month plus (ii) [***] of the sum of the amount of Tax Costs that are reimbursable to Contractor in respect of such month, all as specifically defined in Exhibit B.

Contractor’s Margin” means Contractor’s profit margin for the Work which, in respect of each Margin Milestone shall be calculated as follows:

 

     CM    =    Base Target Price x MP x FP
  Where:   
  CM    =    Contractor’s Margin for the relevant Margin Milestone
  MP    =    the Margin Percentage, as adjusted pursuant to Section 8.2.
  FP    =    the fixed milestone percentage for the relevant Margin Milestone set forth in Appendix 1 of Exhibit D.

Contractor’s Representative” means Contractor’s employee designated by Contractor pursuant to Section 3.8.32.

 

5


 

Corrective Work” has the meaning set forth in Section 20.1.3.

Cost Overrun” means an amount equal to the amount by which the Total Costs exceed the Target Price.

Cost Savings” means an amount equal to the amount by which the Target Price exceeds the Total Costs.

Cover Costs” has the meaning set forth in Section 31.3.

Critical Path” means the longest duration series of interdependent engineering, procurement, construction, Pre-Commissioning, Commissioning and testing activities described in or prepared in accordance with Exhibit E relating to the Work logically connected end to end using critical path method precedence networking techniques agreed to in writing by Owner and Contractor prior to the Notice to Proceed Date, which determines the total duration of the Project Schedule from the commencement of the Work to Facility Substantial Completion or Applicable Deadline, if different.

Customer Commercial Operation Date” means the date on which Owner is obligated under its long-term LNG sales and purchase agreements relating to Phase 2 to make available LNG for sale under such agreements, as notified to Contractor by Owner.

Day” or “day” means a period of twenty-four (24) consecutive hours from 12:00 midnight (Central time), and shall include Saturdays, Sundays and all holidays except that in the event a time period set forth herein expires on a Day that is not a Business Day, such period shall be deemed to expire on the next Business Day thereafter.

Defects” or “Deficiencies” means any components, tools, Materials, installation (including the installation and integration of Owner Furnished Equipment and Materials by Contractor or its Subcontractors), construction, workmanship or Work (including any Corrective Work) that, in Owner’s reasonable judgment, (a) do not conform to the terms of this Agreement or any Warranty or (b) are not of uniform good quality, or designs which fail to conform to the Applicable Codes and Standards, Owner Standards and all other requirements of this Agreement, including Exhibit A (to the extent designed by Contractor or its Subcontractors), application, manufacture or workmanship, or that contain improper or inferior workmanship. Defects and Deficiencies shall not be deemed to include breakdown or damage caused by (i) Owner’s, its Affiliates’ or Owner Contractors’ negligence or Willful Misconduct, (ii) Owner’s failure to supply Owner Furnished Equipment and Materials, or failure of the Owner Furnished Equipment and Materials to perform in accordance with the requirements of this Agreement and of the applicable Owner Contract pursuant to which such Owner Furnished Equipment and Materials were purchased by Owner, or Owner’s failure to perform the Owner Scope of Work, (iii) Owner’s failure to operate or maintain an LNG Production System or the Facility in accordance with operations and maintenance manuals provided to Owner by Contractor or an Owner Contractor, (iv) any repair, alteration or modification by third parties (unless such third party was an Agent For Contractor or approved by Contractor or was retained by Owner to perform such repair, alteration or modification in accordance with this Agreement where Contractor failed to initiate correction of Work), (v) normal wear and tear, or (vi) any effects of the elements on, or use outside

 

6


 

of the design parameters of, an LNG Production System or the Facility, including distortion, corrosion, abrasion, material changes to the operating conditions (such as temperature, pressure, or changes in material product composition).

Deliverables” means all Drawings and Specifications, records, manuals, programs, registers and written procedures required pursuant to the terms of this Agreement (including Exhibit Y) to operate and maintain the Work for the Facility and training of the Facility’s operation and maintenance personnel via classroom and hands-on sessions pursuant to the terms hereof, excluding Deliverables provided under the Owner Contracts.

Demonstration Tests” has the meaning set forth in Exhibit R.

Direct Costs” means the actual, verifiable and documented costs incurred by Contractor with respect to the performance of the Reimbursable Work based upon the labor rates, unit rates and actual out-of-pocket costs and expenses, in each case, as described in more particular detail in Exhibit B-1 and Exhibit C and that are incurred by Contractor in accordance with this Agreement, excluding any Non-Reimbursable Costs.

Dispute” has the meaning set forth in Section 36.1.1.

Dollar” and “$” means the lawful currency of the United States of America.

Drawings and Specifications” means all specifications, calculations, designs, plans, drawings, engineering and analyses, operation and maintenance manuals, original equipment manufacturer manuals, material safety data sheets, operating instructions, system checklists, start-up procedures, Pre-Commissioning, Commissioning procedures and checklists, System Turnover Packages required to be delivered by Contractor hereunder or required to be delivered by an Agent For Contractor under an Agent For Contract, alignment checklists and all other documents of the Work, including the structure and foundation thereof, either (a) described in or attached to this Agreement or any Agent For Contract or (b) prepared or modified by Contractor or any Subcontractor with respect to the Work or any Agent For Contractor with respect to any Agent For Contracts Work, excluding Drawings and Specifications provided under the Owner Contracts.

EAR” has the meaning set forth in Section 40.3.1.

Effective Date” has the meaning set forth in the introductory paragraph hereof.

Environmental Laws” means any Law relating to the regulation or protection of human health, safety, natural resources or the environment or to the remediation, manufacture, generation, production, installation, use, sale, storage, treatment, transportation, Release, threatened Release, exposure to, or disposal of Hazardous Substances.

Estimated Monthly Amount” has the meaning set forth in Section 6.3.1.

Export Controls” has the meaning set forth in Section 40.3.1.

 

7


 

Facility” means (a) the second phase of Owner’s Plaquemines LNG export terminal and liquefaction project, with a nameplate capacity of seven (6.7) MTPA of LNG, to be located at the Job Site and more specifically described as the fully operational, complete project (including Materials and Owner Furnished Equipment and Materials incorporated therein) to be designed, engineered, procured, constructed, pre-commissioned, tested, delivered and warranted under this Agreement in order to successfully pass the Performance Tests and meet or exceed the requirements set forth in Exhibit A, and consisting of the Liquefaction Train System, the LNG Storage Tanks, the Pre-Treatment System and the marine terminal and including all Materials necessary to safely and efficiently transport and process Feed Gas through each LNG Production System, load and store LNG in the LNG Storage Tanks, transport LNG to, and load LNG on, an LNG Tanker, and otherwise process, transport, store load and unload LNG and Feed Gas, all as more particularly described in Exhibit A together with the supporting improvements and interconnections related thereto, as specifically addressed in the Exhibits hereto, and (b) the Power Plant.

Facility Mechanical Completion” means the acceptance by Owner of the Facility after satisfaction of the applicable conditions set forth in Exhibit P and Section 19.1.

Facility Mechanical Completion Date” means the date on which Facility Mechanical Completion occurs in accordance with Section 19.1.

Facility Performance Tests” has the meaning set forth in Section 15.3.4.

Facility Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.3 as liquidated damages for the delay in the achievement of Facility Substantial Completion.

Facility Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(c).

Facility Substantial Completion” means the completion of the Facility (excluding, for the avoidance of doubt, the Phase 1 Facility) in accordance with and to the extent set forth in Section 19.2.

Facility Substantial Completion Date” means the date on which Facility Substantial Completion occurs in accordance with Section 19.2.

Facility Substantial Completion Deadline” means the date identified on Exhibit D.

Feed Gas” means natural gas, in gaseous form, which consists of gas transported by natural gas pipelines in the United States of America.

Feed Gas Interconnection” means the installation of the Materials to the Pipeline Tie Point(s) and all other activities necessary to effect interconnection of the Facility with the civil, mechanical, electrical and control systems of the Gator Express Pipeline.

Field Services Agreement” means the Field Services Agreement, dated as of May 2, 2022, by and between Owner and BH.

 

8


 

Final Completion” means the completion of the Facility in accordance with and to the extent set forth in Section 19.4.

Final Completion Date” means the date on which Final Completion occurs in accordance with Section 19.4.

Final Completion Deadline” means the date that is [***] days after the Facility Substantial Completion Date.

Final Request for Payment” has the meaning set forth in Section 6.7.

Financial Closing Date” means the closing date for the Financing by the Lenders, at which time all conditions precedent to the drawing of funds thereunder have been satisfied or waived and the initial funds contemplated by the Financing are disbursed to Owner.

Financing” has the meaning set forth in Article 39.

Financing Deliverables” has the meaning set forth in Article 39.

Force Majeure Event” means any act, event or condition that (a) arises after the Effective Date and (b) has an impact which will actually, demonstrably and adversely affect a Party’s ability to perform its obligations in accordance with this Agreement (excluding obligations to pay money due) or will actually, demonstrably and adversely affect the Critical Path, in each case, to the extent that such act, event or condition (i) is beyond the reasonable control of the Party relying thereon, (ii) is not the result of any unreasonable acts, omissions or delays of the Party relying thereon (or any Third Party over whom such Party has control, including any Subcontractor), (iii) is not an act, event or condition, the risks or consequences of which such Party has expressly agreed to assume hereunder, or (iv) that could not be avoided by the exercise of reasonable precautions, efforts and measures (including planning, scheduling and rescheduling), whether before, after or during such act, event or condition. “Force Majeure Event” includes the following (if the conditions and requirements described above are satisfied): hurricanes, named tropical storms, floods, storm surge, tsunamis, lightning strike, volcanic eruptions, tornados, or other unusually severe conditions; government decreed official state of emergency or other governmental action of a Government Authority; fire, earthquakes and explosions; epidemics (including the epidemic known as COVID-19); contamination by nuclear, chemical, or biological cause; acts of war (whether declared or undeclared), including acts of war/military conflicts arising between the Russian Federation and Ukraine; civil unrest at or in the immediate proximity of the Job Site; accidents of navigation; sabotage or terrorism; and strikes, work stoppages or other labor actions that are not directed solely at Contractor or any Subcontractor; and Change in Law. Notwithstanding the foregoing, “Force Majeure Event” does not include (i) strikes, work stoppages (or deteriorations), slowdowns or other labor actions directed solely at Contractor or any Subcontractor or any Agent For Contractor solely involving the employees of Contractor or any Subcontractor or any Agent For Contractor, (ii) weather conditions (other than those expressly defined as Force Majeure Events above) which could reasonably be anticipated by experienced professional design and construction contractors familiar with building comparable facilities on the Gulf Coast of the United States of America, (iii) any Job Site Condition or event arising therefrom, (iv) the occurrence of any manpower, craft labor or Materials shortages (unless

 

9


 

otherwise caused by a Force Majeure Event), (v) any failure by Contractor or any Agent For Contractor to obtain and/or maintain any Permit it is required to obtain and/or maintain hereunder, (vi) any delay, default or failure (direct or indirect) in obtaining Materials or of any Subcontractor or any other delay, default or failure (financial or otherwise) of a Subcontractor or Agent For Contractor (unless otherwise caused by a Force Majeure Event), (vii) to the extent arising prior to the Effective Date, any economic sanctions, Tax imposed or other trade measures (including, but not limited to, the revocation of permanent normal trade relations or other actions) taken by any country or intergovernmental or supranational organization in respect to the Russian Federation’s or any other aggressor country’s invasion of Ukraine, any economic sanctions, Tax imposed or other trade measures (including, but not limited to, the revocation of permanent normal trade relations or other actions) taken by any country or intergovernmental or supranational organization in respect to the Russian Federation’s or any other aggressor country’s invasion of Ukraine or (viii) changes in market conditions.

Gator Express Pipeline” means, collectively, the natural gas pipelines interconnected with the Facility, as more specifically described in Exhibit A.

Geotechnical Reports” means those reports furnished by Owner to Contractor prior to the execution of this Agreement, as further described in Exhibit M.

Government Authority” means any agency, authority, department, court, tribunal, ministry, legislative body, commission, instrumentality, public person, statutory or legal entity, person (whether autonomous or not), or other subdivisions of any of the above having a regulatory interest in or jurisdiction over any Party, the Job Site, the performance of the Work, or the Facility (or the construction or operation thereof).

Government Official” has the meaning set forth in Section 40.1.3.

Gross Negligence” means any act or failure to act by a Person which (i) seriously and substantially deviates from a diligent course of action, and (ii) was in reckless disregard of or with wanton indifference to, harmful consequences such Person knew, or should have known, such act or failure would have had.

Hazardous Substances” means any element, compound, mixture, solution, particle or substance:

(a) which is or may become dangerous, harmful or potentially dangerous or harmful to the health and welfare of life, natural resources or the environment, such as, but not limited to, explosives, petroleum products, radioactive, corrosive, flammable, infectious, carcinogenic, or mutagenic materials, hazardous wastes, toxic substances and related materials, and including any substance or material included within the definitions of “hazardous substances,” “hazardous wastes,” “solid wastes,” “hazardous materials,” “chemical substances,” “hazardous pollutants” or “toxic pollutants” in any Law, including any Law relating to the protection of human health, natural resources or the environment;

(b) the presence or Release of which requires investigation or remediation under any applicable Law;

 

10


 

(c) which is listed, defined, regulated or forms the basis for liability under any applicable Law relating to the protection of human health, natural resources or the environment; or

(d) the presence of which on the Job Site causes or threatens to cause a nuisance upon the Job Site or to the adjacent properties or poses or threatens to pose a hazard to the health or safety of Persons on or about the Job Site or on or about the adjacent properties.

HSSE” has the meaning set forth in Section 11.2.2.

HSSE Program” has the meaning set forth in Section 11.2.1.

ICC” means the International Chamber of Commerce.

Indemnified Liens” has the meaning set forth in Section 6.4.1.

Independent Engineer” means the engineering firm designated by the Lenders to monitor the progress of the Work and conformity of the Work with Owner Standards and the requirements and specifications contained herein.

Initial Request for Payment” means the first Request for Payment that is issued simultaneously with the Notice to Proceed.

Initial Site Access Date” means October 1, 2021.

Intellectual Property” means all United States and foreign intellectual property, including all (a) inventions (whether or not patentable or reduced to practice), improvements, patents and industrial designs (including utility models, designs, and industrial property) and patent and industrial design applications, and inventions and patent disclosures, together with all renewals, reissues, reexaminations, provisionals, divisionals, revisions, continuations, continuations-in-part, and extensions thereof; (b) works of authorship (whether or not copyrightable), registered and unregistered copyrights, mask works, database rights, and moral rights, together with all applications therefor and renewals thereof; and (c) trade secrets, confidential or proprietary information (including unpublished patent applications, technical data, customer and suppliers lists, pricing and cost information, and business and marketing plans and proposals), technology, know-how, processes, techniques, protocols, specifications, data, compositions, industrial models, architectures, layouts, designs, drawings, plans, ideas, research and development, formulae, algorithms, models, and methodologies.

Intellectual Property Claim” means any claim, demand, suit or legal action to the extent arising out of or based on any actual or alleged unauthorized disclosure, use or misappropriation of any Intellectual Property, or any actual or alleged infringement or other violation of any right in, to or under, any Intellectual Property of any other Person that: (a) concerns any Materials, Deliverables, Inventions or other services or information provided by Contractor, any of its Affiliates, or any Subcontractor under this Agreement or by any Agent For Contractor under any Agent For Contract; (b) is based upon or arises out of the performance of the Work by Contractor, any of its Affiliates, or any Subcontractor or Agent For Contractor, including the use of any tools or other implements of construction by Contractor, any of its Affiliates, or any Subcontractor or

 

11


 

any Agent For Contractor; (c) is based upon or arises out of the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem or component thereof) by Contractor or any of its respective Affiliates or Subcontractors under this Agreement or by any Agent For Contractor under any Agent For Contract or their use of any Contractor Intellectual Property in connection therewith; or (d) is based upon or arises out of Owner’s exercise of its rights pursuant to and in accordance with Article 29.

Interim Milestone” means a Schedule Milestone identified as an Interim Milestone on Appendix 2 of Exhibit D.

Interim Milestone Bonus” means a bonus payment in an amount equal to [***], as such amount may be adjusted pursuant to Sections 7.1.2 and 7.1.3.

Inventions” has the meaning set forth in Section 29.1.

Job Site” means the portion of Owner’s real property interests on which the Facility is to be located, plus the laydown areas, rights-of-way, easements and other property rights affixed, connected or associated therewith and such additional areas as may, from time to time, be designated in writing by Owner for Contractor’s use hereunder, as more fully described in Exhibit A.

Job Site Conditions” has the meaning set forth in Section 3.3.

JV Agreement” means that certain Limited Liability Company Agreement for KZJV LLC, entered into between the JV Members on March 16, 2021.

JV Member” means each of Kellogg Brown & Root LLC, a Delaware limited liability company, and Zachry Industrial, Inc., a Texas corporation, and “JV Members” means both of them, collectively.

Key Personnel” means the employees of Contractor named in Exhibit K.

Late Payment Rate” means the lesser of (a) two percent (2%) above the per annum Prime Rate reported daily in The Wall Street Journal, or (b) the maximum rate permitted by Law.

Law” means (a) any applicable statute, law, common law, rule, regulation, code, ordinance, judgment, decree, writ, order or the like of any Government Authority and the official interpretations thereof or (b) any official requirements or conditions on or with respect to the issuance, maintenance or renewal of any applicable Permit issued by any Government Authority including laws related to Taxes, import or export charges (including any tariffs, levies and duties).

Lenders” means (a) any Person that does or proposes to provide Financing in respect of the Facility and/or the general business and operations of Owner or its Affiliates (including any refinancing thereof), including any export credit agency, funding agency, bondholder, insurance agency, underwriter, investor, commercial lender or similar institution, together with any agent or trustee for such Person and (b) any provider of any hedging arrangement entered into in connection with the arrangements described in clause (a) above, including an interest rate swap transaction or a forward interest rate swap transaction, in each case, together with any agent or trustee for such provider.

 

12


 

Limited Notice to Proceed” has the meaning set forth in Section 4.2.1.

Liquefaction Train” means the Mixed Refrigerant compression package, including the cold box, surge vessel and other equipment producing approximately [***] MTPA of LNG at design outlet pressure and ambient design conditions of [***] degrees Fahrenheit and [***] relative humidity, at sea level, as further described in Exhibit A.

Liquefaction Train System” means the Mixed Refrigerant compression package, including the cold box, surge vessel and other equipment in a configuration of twelve (12) Liquefaction Trains capable of producing an aggregate of approximately [***] MTPA of LNG at design conditions, as further described in Exhibit A and Exhibit R.

LNG” means liquefied natural gas meeting the requirements described in Exhibit A.

LNG Production System” means LPS5 or LPS6, as applicable.

LNG Production System Handover Package” means, with respect to each of LPS5 or LPS6, the equipment, Materials and Owner Furnished Equipment Materials described in Exhibit S.

LNG Production System Mechanical Completion” means the acceptance by Owner of an LNG Production System after satisfaction of the applicable conditions set forth in Section 18.1 and Exhibit P.

LNG Production System Mechanical Completion Certificate” means the certificate provided by Contractor in the form of Exhibit F-11 certifying the satisfaction of each of the requirements required to achieve LNG Production System Mechanical Completion in Section 18.1.

LNG Production System Mechanical Completion Date” means, with respect to an LNG Production System, the date on which LNG Production System Mechanical Completion of such LNG Production System occurs in accordance with Section 18.1.

LNG Production System RFSU” means, with respect to an LNG Production System, all of the following conditions are satisfied: (a) Contractor has completed all applicable Work in accordance with this Agreement, including Exhibit P, to ensure that such LNG Production System is ready to receive and utilize Feed Gas, (b) Contractor has achieved LNG Production System Mechanical Completion, and (c) Contractor has delivered to Owner an LNG Production System RFSU Certificate, as required in Section 18.2.

LNG Production System RFSU Certificate” means the certificate provided by Contractor in the form of Exhibit F-12 in advance of the introduction of Feed Gas for Commissioning.

LNG Production System Substantial Completion” means the completion of an LNG Production System in accordance with and to the extent set forth in Section 18.3.

 

13


 

LNG Production System Substantial Completion Date” means, with respect to an LNG Production System, the date on which LNG Production System Substantial Completion of such LNG Production System occurs in accordance with Section 18.3.

LNG Production System Substantial Completion Deadline” means the LPS5 Substantial Completion Deadline or the LPS6 Substantial Completion Deadline, as applicable.

LNG Storage Tank” means one (1) of the two (2) cryogenic LNG storage tanks designed and field erected in accordance with this Agreement, as more particularly described in Exhibit A.

LNG Storage Tank Cooldown” has the meaning set forth in Section 18.2.2.

LNG Tanker” means an ocean-going vessel suitable for the transportation of LNG which conforms to the specifications set forth in Exhibit A.

Loading Rate Test” has the meaning set forth in Exhibit R.

Losses” means any and all losses, liabilities, damages, costs, charges, expenses, fines, interest, awards and penalties, which are the result of or arise from any actions, suits, claims, demands, causes of action, litigation, lawsuits, administrative proceedings or administrative investigations.

LPS5” means the systems and sub-systems comprising a portion of the Facility and including the first [***] Blocks that are collectively identified as such in Exhibit A.

LPS5 Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.1 as liquidated damages for the delay in the achievement of LNG Production System Substantial Completion of LPS5.

LPS5 Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(a).

LPS5 Substantial Completion Date” means the date on which LNG Production System Substantial Completion is achieved for LPS5.

LPS5 Substantial Completion Deadline” means the date so identified on Exhibit D.

LPS6” means the systems and sub-systems comprising a portion of the Facility and including the final [***] Blocks that are collectively identified as such in Exhibit A.

LPS6 Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.2 as liquidated damages for the delay in the achievement of LNG Production System Substantial Completion of LPS6.

LPS6 Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(b).

 

14


 

LPS6 Substantial Completion Date” means the date on which LNG Production System Substantial Completion is achieved for LPS6.

LPS6 Substantial Completion Deadline” means the date so identified on Exhibit D.

LTS PO” means that certain Purchase Order Contract for the Sale of the Liquefaction Train System, dated as of August 5, 2022, by and between Owner and BH.

Major Subcontract” means (a) any Subcontract providing services or Materials for the Work having an aggregate value in excess of [***] , (b) multiple Subcontracts with the same Subcontractor (including any Subcontractor that is an Affiliate of Contractor) providing services or Materials for the Work having an aggregate value in excess of [***] for the purposes of Sections 6.3.3, 6.7, 19.4.1(i) and 23.1.1, “Major Subcontract” means any Subcontract providing services or Materials for the Work having an aggregate value in excess of [***] .

Major Subcontractor” means each Subcontractor that is party to a Major Subcontract.

Make Good Commencement Date” has the meaning set forth in Section 15.3.4.

Margin Milestones” means the events to be achieved by Contractor for payment of Contractor’s Margin as defined in Exhibit A and included as Appendix 1 of Exhibit D.

Margin Percentage” means, initially, [***] , as such percentage may be adjusted pursuant to this Agreement.

Material Change” means any proposed Change Order or other amendment, supplement or modification to this Agreement which, (a) delays, extends or changes an Applicable Deadline, (b) modifies the requirements for successfully passing any Demonstration Tests or Performance Tests or the manner in which any Demonstration Tests, or Performance Tests are performed or the results thereof are measured, (c) diminishes the scope or duration of any Contractor warranty, (d) alters the amount, timing or manner of payment of any Contractor liquidated damages, (e) causes the Work (or any portion thereof) to materially deviate from the requirements set forth in Exhibit A, (f) increases the Target Price by more than [***] for an individual change or, when aggregated with all other changes previously effected, causes the Target Price to increase by an amount that is more than [***] or (g) otherwise materially diminishes, lessens or waives any liability or obligation of Contractor under this Agreement or any right or benefit of Owner hereunder. The term “Material Change” is a term distinct and separate from references herein to “material adverse change,” and shall in no way be construed or applied to define the word “material” or “materially” when used herein.

Materials” means those equipment, materials, supplies, apparatus, machinery, parts, tools (including any special tools), components, instruments, appliances, systems, construction and testing-related spare parts and appurtenances thereto (a) required for prudent design, engineering, procurement, construction, installation, Pre-Commissioning, Commissioning, testing, delivery and operation, maintenance and repair of the Work and for the installation, Pre-Commissioning at the Job Site, Commissioning, testing, and operation of the Facility in accordance with Owner Standards and supplied under the terms of this Agreement, (b) described in or required as part of the Work by Exhibit A, excluding, in each case, the Owner Furnished Equipment and Materials.

 

15


 

Mixed Refrigerant” means a mixture of gases or liquids, including ethylene, propane, i-pentane, nitrogen and other gases as may be required to operate a Liquefaction Train.

MMBtu” means one million British Thermal Units.

MMSCFD” means Million Standard Cubic Foot per Day.

Month N” means the calendar month during which the Notice to Proceed Date occurs or a subsequent month, as applicable, during which Work is performed.

Month N+2” has the meaning set forth in Section 6.3.1.

Monthly Progress Report” has the meaning set forth in Section 13.3.

MTPA” means million Tonnes of LNG per annum.

MW” means one (1) megawatt or one million (1,000,000) watts.

Non-Reimbursable Costs” has the meaning set forth in Exhibit B-1.

Notice” means a written communication from one Party to another Party required or permitted by this Agreement, conforming to the requirements of Article 38.

Notice of Contract” has the meaning set forth in Section 3.8.56.

Notice of Dispute” has the meaning set forth in Section 36.1.1.

Notice to Proceed” has the meaning set forth in Section 4.1.1.

Notice to Proceed Date” has the meaning set forth in Section 4.1.1.

Owner” has the meaning set forth in the introductory paragraph hereof, and includes its legal successors and those permitted assigns as may be designated by Owner, in writing, pursuant to the terms of this Agreement.

Owner Caused Delay” means any delay in the performance and completion of the Work by the Applicable Deadline that is directly and demonstrably caused by an act, omission or failure by Owner, Owner Contractors or any party for whom Owner is responsible hereunder, to perform its obligations hereunder, including as a result of: (i) the failure of Owner to obtain a Permit that Owner is required to obtain hereunder; (ii) the failure of the Owner Furnished Equipment and Materials to perform in accordance with the requirements of the Owner Contract(s) pursuant to which such Owner Furnished Equipment and Materials were purchased by Owner; (iii) the failure by Owner to perform the Owner Scope of Work, including the supply of the Owner Furnished Equipment and Materials, on the agreed schedule therefor; (iv) the failure of BH to declare “Ready for Test” (as that term is defined in the LTS PO) in relation to the liquefaction trains comprising any LNG Production System within [***] days of Contractor achieving LNG

 

16


 

Production System RFSU in respect of such LNG Production System, as described in Section 18.2.1 (a “BH Testing Delay”); (v) the failure of an Owner Contractor to timely perform its obligations under its respective Owner Contract(s); or (vi) the failure of Owner to approve change orders or claim settlements with Subcontractors and Agent For Contractors in accordance with this Agreement, which failure actually, demonstrably and adversely affects the Critical Path; provided, however, that, notwithstanding the foregoing, “Owner Caused Delay” does not include: (a) any act or omission (except as to item (vi) above) that is permitted under, and is taken or caused in accordance with, the terms of this Agreement; (b) any act or omission of Owner acting under or in accordance with any written instructions from Contractor or the Contractor’s Representative; or (c) any act, omission or failure by Owner, Owner Contractors or any party for whom Owner is responsible that does not affect the Critical Path (except with respect to (iv) above, in which case Contractor is entitled to a day for day extension as described in Section 12.1.1).

Owner Contractor” means any party to an Owner Contract (other than Owner). For the avoidance of doubt, the term Owner Contractor does not include Agent For Contractors.

Owner Contracts” means:

(a) the Construction Agreement relating to marine works (Phase 2), dated as of October 10, 2022, between Owner and Weeks-Massman, a Joint Venture;

(b) the LTS PO;

(c) that certain Purchase Order Contract for the Sale of the Power Island System, dated as of February 3, 2022, between Owner and BH;

(d) the LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 2), dated as of April 12, 2019, by and between CB&I LLC and Owner;

(e) the Engineering and Procurement Agreement (Phase 2), dated as of April 12, 2019, by and between UOP LLC and Owner;

(f) the Field Services Agreement;

(g) any site works agreement(s) entered into between Owner and the relevant Owner Contractor (which agreement(s) shall be deemed to be Owner Contracts even if otherwise stated to the contrary therein);

(h) the Purchase Order Contract for the Sale of Booster Compression System, dated as of September 30, 2022, by and between BH and Owner; and

(i) the Purchase Order Contract for the Sale of BOG (Boil Off Gas) Compression Units, to be entered into by and between Siemens Energy and Owner.

Owner Designees” means the Independent Engineer, Owner’s Representative, any Affiliate of Owner so designated in writing by Owner and all other consultants, contractors, agents or representatives Owner or its Affiliate employs or appoints in connection with the performance of Owner’s rights and obligations under this Agreement. For the avoidance of doubt, the term Owner Designees does not include any Agent For Contractor.

 

17


 

Owner Furnished Equipment and Materials” means the equipment, materials or components of the Facility that are to be furnished or procured by Owner or the Owner Contractors under the Owner Contracts as part of the Owner Scope of Work.

Owner Indemnitees” means Owner, Owner’s Representatives, the Lenders, the Independent Engineer and all Affiliates, officers, directors, employees and agents thereof.

Owner Protocols” means the written protocols for the Contractor’s operation of the Facility during the period commencing on the LNG Production System Substantial Completion Date for the first LNG Production System to achieve LNG Production System Substantial Completion and ending on the Facility Substantial Completion Date, as described in Exhibit T.

Owner Scope of Work” means the services and other activities performed by or on behalf of Owner that are specifically identified as the “Owner Scope of Work” in Exhibit A. For the avoidance of doubt, the Owner Scope of Work does not include the Agent For Contracts Work.

Owner Standards” unless otherwise specified in Exhibit A, means those sound and prudent practices, methods, specifications or standards of design, engineering, construction, performance, safety, workmanship, equipment and components prudently and generally engaged in or observed by the majority of the professional engineering and construction contractors in the LNG and electric power industry in the United States of America for similar types of LNG export and liquefaction facilities and power generation facilities that at a particular time, in the exercise of reasonable judgment, would have been expected to accomplish the desired result in a manner consistent with applicable Laws, Applicable Codes and Standards, Permits, reliability, health and safety, and environmental protection and local conditions, but such standards are not limited to the best or optimum practice or method to the exclusion of all others. Without limiting the foregoing, the Facility or any portion thereof or any technical specifications shall not be required to meet any specifications less stringent than the specifications set forth herein. Owner Standards are not intended to be limited to the optimum practices, methods, or standards to the exclusion of all others, but rather to be a spectrum of reasonable and prudent practices, methods, and standards employed by firms in the engineering and construction industry familiar with building comparable facilities on the Gulf Coast of the United States of America.

Owner’s Representative” means Owner’s employee or representative designated by Owner pursuant to Section 3.7.3.

Parties” means Owner and Contractor collectively, and “Party” means Owner or Contractor, individually, as applicable.

Payment Bond” means the Performance and Payment Bond described in Section 9.2.3.

Performance Bond” means the Performance and Payment Bond described in Section 9.2.2.

Performance and Payment Bonds” has the meaning set forth in Section 9.2.1.

 

18


 

Performance Security” means the security provided by Contractor to Owner in the form of the (a) Performance and Payment Bonds and (b) the Contractor Guarantees.

Performance Tests” has the meaning set forth in Exhibit R.

Permit” means any authorization, consent, approval, license, ruling, permit, exemption, filing, variance, order, judgment, decree, publication, condition, notice to, declaration or registration of or with or regulation by or of any Government Authority relating to the acquisition, ownership, occupation, construction, Pre-Commissioning, Commissioning, testing, operation or maintenance of the Facility.

Permitted Liens” means materialmen’s, mechanics’, workers’, repairmen’s, employees’ or other similar liens filed by a Subcontractor arising in the ordinary course of business for amounts not yet due or for amounts being contested in good faith by appropriate proceedings, so long as, in the case of any such contest, (a) Contractor shall have posted or provided to Owner a letter of credit, bond (in form and substance acceptable to Owner) or other security reasonably satisfactory to Owner and the Independent Engineer in an amount equal to such contested lien and (b) such proceedings in Owner’s reasonable judgment shall not involve any danger of the sale, forfeiture or loss of any part of the Facility, title thereto or any interest therein and shall not interfere with the timely completion, use or disposition of the Facility.

Person” means an individual, a corporation, a limited liability company, an unincorporated organization, a partnership, a joint venture, an association, a trust or any other entity or organization, including a Government Authority.

Phase 1 Agreement” means that certain Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January 7, 2022, between Owner and Contractor.

Phase 1 Facility” means the “Facility” (as such term is defined in the Phase 1 Agreement).

Phase 2” has the meaning set forth in the recitals.

Pipeline Contractor” means the Person engaged to engineer, procure and construct the Gator Express Pipeline.

Pipeline Tie Point(s)” means the point(s) where the systems of the Facility are interconnected with the Gator Express Pipeline, as more specifically described in Exhibit A.

Power Plant” means (i) two (2) [***] gas turbines and associated generators, two (2) [***] steam turbines and associated generators, five (5) HRSG’s [***], two (2) air-cooled condensers and (ii) the associated pumps, piping, valves, instrumentation, electrical systems, and control systems, including any required auxiliary or ancillary equipment, as more specifically described in Exhibit A.

Pre-Approved Site Workmeans the site preparation work so identified in Exhibit A.

 

19


 

Pre-Commissioning” means the checks, tests and calibrations set forth in Exhibit P and required to be performed as part of the Work prior to performing the Commissioning of an LNG Production System, including all applicable safety related and utility components being placed in service and made operational, completion of all function testing/static commissioning activities that do not involve the introduction of hydrocarbons into systems, such as loop checks, operating control and emergency actuated valves, panel function tests, energizing electrical equipment and running motors without loads, all carried out on a single discipline basis, typically by system/subsystem, and the completion of all ‘A’ and ‘B’ inspection and test records and agreed punch lists.

Pre-Existing Hazardous Substance” means a Hazardous Substance that existed or was present on, at or under the Job Site on or before the Notice to Proceed Date, excluding any Hazardous Substance Released by Contractor or its Subcontractors on the Job Site after the Initial Site Access Date and prior to the Notice to Proceed Date.

Pre-Treatment System” means an acid gas treating, dehydration and regeneration system, and heavy hydrocarbon removal system, as further described in Exhibit A.

Primary Milestone” means a Schedule Milestone identified as a Primary Milestone on Appendix 2 of Exhibit D.

Primary Milestone Bonus” means a bonus payment in an amount equal to [***] , as such amount may be adjusted pursuant to Sections 7.2.2 and 7.2.3.

Project Schedule” means the schedule for the performance of the Work developed, delivered and maintained in accordance with Exhibits D and E.

Punch List Items” means those minor items of the Work identified by Owner or Contractor as requiring completion or correction prior to Final Completion, which items do not affect the performance or safe and continuous operation of an LNG Production System or the Facility.

Qualified Surety” means a U.S. bank, insurance company, or other financial institution which is rated at least “A” by Standard & Poor’s Ratings Group, Inc. (or a comparable rating from another internationally recognized ratings agency).

Quality Management Plan” has the meaning set forth in Section 10.1.

Ready for Commissioning Certificate” means the certificate provided to Owner by Contractor, after LNG Production System Mechanical Completion and completion of Pre-Commissioning of an LNG Production System, certifying that such LNG Production System is ready for Commissioning.

Reimbursable Costs” means Direct Costs that are reimbursable to Contractor, as described in Exhibit B-1.

Reimbursable Work” means the Work, excluding the Corrective Work.

 

20


 

Release” means any emission, spill, seepage, leak, escape, leaching, discharge, injection, pumping, pouring, emptying, dumping, disposal, migration, or release of Hazardous Substances from any source into or upon the indoor or outdoor environment.

Relied Upon Information” has the meaning set forth in Exhibit M.

Representatives” means, with respect to a Party, such Party’s Affiliates, directors, officers, and employees.

Request for Payment” means the Contractor’s monthly submission to Owner of all documentation and materials required by Section 6.3 requesting payment, which request for payment shall be in the form provided in Exhibit F-7.

Satellite Facility” means each site located in the vicinity of the Job Site that is jointly designated by Owner and Contractor to be utilized by Contractor and/or its Subcontractors for the positioning, storage and/or transshipment of certain equipment and materials necessary for the performance of the Work.

Schedule Bonus” means an Interim Milestone Bonus, a Primary Milestone Bonus or a Super Primary Milestone Bonus, as applicable.

Schedule Bonus Cap” means, as of any date, an amount equal to the lesser of (i) [***] and (ii) the positive difference between (x) [***] and (y) the aggregate amount of schedule bonuses earned by Contractor pursuant to that certain Second Amended and Restated Engineering, Procurement and Construction Agreement dated as of January 7, 2022.

Schedule Delay Liquidated Damages” means the LPS5 Schedule Delay Liquidated Damages, the LPS6 Schedule Delay Liquidated Damages and the Facility Schedule Delay Liquidated Damages.

Schedule Milestone” an event to be achieved by Contractor for payment of a Schedule Bonus pursuant to and in accordance with Article 7, as described on Appendix 2 of Exhibit D.

SDN” has the meaning set forth in Section 40.1.1.

“Senior Supervisory Personnel” means Contractor’s project director, project engineering manager, project construction manager and other Contractor personnel identified in Exhibit K.

Serial Defect” has the meaning set forth in Section 20.2.6.

Severe Injury” means an injury or accident that requires, or is reasonably likely to require, a formal admission to a hospital or clinic for care or treatment, excluding treatment solely in an urgent care center.

Shipping Information” has the meaning set forth in Section 3.10.

Spare Parts” has the meaning set forth in Section 3.9.1.

 

21


 

Subcontract” means an agreement (including a purchase order) (a) by Contractor with a Subcontractor for the supply of any equipment or materials or the performance of any portion of the Work or (b) by a Subcontractor with a lower tier of Subcontractor for the supply of any equipment or materials or the performance of any portion of the Work.

Subcontractor” means any Person (other than Contractor) that performs any portion of the Work, whether hired directly by Contractor, or by a Person hired by Contractor and including every tier of Subcontractor, sub-subcontractors, vendors, suppliers and so forth.

Super Primary Milestone” means a Schedule Milestone identified as a Super Primary Milestone on Appendix 2 of Exhibit D.

Super Primary Milestone Bonus” means a bonus payment in an amount equal to [***] , as such amount may be adjusted pursuant to Sections 7.3.2 and 7.3.3.

Surplus Construction Materials” has the meaning set forth in Section 3.8.15.

Suspension Notice” means a notice of suspension provided by Owner to Contractor in accordance with Section 17.1.1 or 17.1.2.

Suspension Period” has the meaning set forth in Section 17.1.1.

System Turnover Package” means those binders defined by the individual system process and instrument diagrams (P&ID) and electrical single line diagrams in which Contractor compiles all relevant quality assurance and quality control test results which show that the system and its components were installed and tested in full conformance with the design drawings, vendor requirements, Owner Standards and this Agreement.

Tank Three” means the LNG Storage Tank so identified on the plot plan provided in Exhibit A.

Tank Four” means the LNG Storage Tank so identified on the plot plan provided in Exhibit A.

Target Price” has the meaning set forth in Section 6.1.1.

Tax” means any present or future tax (including any stamp duty, income, payroll, sales, use, value added, consumption or goods and services tax), tariff, levy, impost, duty, charge, fee, deduction or withholding of whatever nature, including any such income tax, payroll tax, value added tax, sales tax, stamp tax, customs duty, import duty, export duty, withholding tax, excise tax, property tax, registration fee or license, water tax, sanitary tax, lighting tax or environmental, energy or fuel tax, which is levied, collected, assessed or imposed by a Government Authority at any time, and any interest, penalty, charge, fee or other amount imposed, collected, withheld, assessed or made on or in respect of any of the above.

Tax Costs” means any sales tax or sales and use tax levied by any U.S. state or any political subdivision thereof that is incurred by Contractor or any Agent For Contractor in the performance of the Work or the Agent for Contracts Work.

 

22


 

Third Party” means any party other than an Owner Indemnitee, a Contractor Indemnitee, an Owner Contractors or an Owner Contractors’ subcontractors. For the avoidance of doubt, the term Third Party does not include any Agent For Contractor.

Tonne” means metric ton and is defined as 2,204.6 lbs.

Total Cost Exclusions” means for the purposes of Section 8.1.2: (i) all or any portion of a Schedule Bonus paid to or forfeited by Contractor as described in Article 7; (ii) Taxes, if paid by Contractor which will then be reimbursed by Owner, unless such Taxes constitute Non-Reimbursable Costs; (iii) costs incurred by Contractor or assigned by Owner with respect to Owner Furnished Equipment and Materials, including with respect to defects or deficiencies, or lack of performance of, Owner Furnished Equipment and Materials; (iv) uninsured losses and deductibles arising under the Construction and Erection All Risk Insurance Policy, Owner Controlled Insurance Program for Commercial General Liability Policy, marine cargo, and any permanent property insurance policy, each procured by Owner; (v) Direct Costs paid to or paid by Contractor for Work subject to a claim against the Builder’s Risk Insurance Policy, Owner Controlled Insurance Program for Commercial General Liability Policy Marine Cargo, or Permanent Property Insurance policies; (vi) amounts reimbursed or credited to Contractor by Subcontractors (including back charges for Work performed by Contractor to complete Subcontractor work or remedy Subcontractor Defects and Deficiencies, liquidated damages or otherwise); and (vii) any other cost expressed to be excluded from the calculation of Total Costs hereunder; provided that, in the case of Defects or Deficiencies, the Direct Costs paid to Contractor or costs incurred by Owner in order to correct the Defects or Deficiencies in accordance with Section 20.5 be included in the calculation of “Total Costs”.

Total Costs” has the meaning set forth in Section 8.1.2.

Treated Gas” means natural gas that has been treated (through removal of compounds or otherwise) for quality to make it suitable for feed into a Liquefaction Train.

U.S.” has the meaning set forth in Section 40.3.1.

UOP” means UOP LLC or any of its Affiliates.

Warranties” has the meaning set forth in Section 20.2.7.

Warranty Period” means the period that commences on the relevant LNG Production System Substantial Completion Date and ends [***] after the Facility Substantial Completion Date, subject to any extension thereof pursuant to Sections 20.2.6 and 20.4.

Willful Misconduct” means in relation to the Person concerned, a deliberate act or omission not justifiable by any circumstances that is likely to cause foreseeable injury or harm; but shall not include any unintentional act, omission or mistake made by any Person.

Work” means all acts or actions required to be performed by Contractor and its Subcontractors under this Agreement or by the Agent For Contractors, or necessary for Contractor to complete its obligations hereunder, including the integration and installation of Owner Furnished Equipment and Materials and the design and engineering (including verification of the

 

23


 

integration design for purpose of confirming the Facility Performance Tests requirements and undertaking of a debottlenecking or plant integration constraint study of the Facility for the purpose of maximizing the performance of the Facility, and such other studies, as applicable, described in Exhibit A or as Owner may reasonably request, and implementing the recommendations of such studies), procurement, manufacturing, preservation, packing and transportation, construction, training, erection, testing, Pre-Commissioning, Commissioning, start-up, operation, and guaranteeing of the Facility in accordance with Article 15, whether at the Job Site or elsewhere, until Final Completion and satisfaction of Contractor’s warranty obligations during the Warranty Period, as more fully described in Exhibit A and this Agreement, and such other incidental acts as may be necessary to provide Owner with a fully operational and integrated Facility which successfully passes the Performance Tests, at least meets the Owner Standards and otherwise satisfies the conditions set forth herein. The term “Work” shall also include providing security of the Job Site and construction management services relating to the scheduling and coordination of the work and services performed by the Owner Contractors under the Owner Contracts and the administration of the performance by each Owner Contractor of its obligations of the relevant Owner Contract(s). Notwithstanding the foregoing, the term “Work” shall not include: (i) the supply or performance (except as it relates to installation or integration or as described in the immediately preceding sentence) of the Owner Furnished Equipment and Materials; (ii) the performance of the Owner Scope of Work; or (iii) any other obligation of Owner specifically described herein.

 

2.

AGREEMENT; EXHIBITS; CONFLICTS.

 

2.1

LANGUAGE OF AGREEMENT.

This Agreement and all documentation to be supplied hereunder (including the operation and maintenance manuals which Contractor provides to Owner pursuant to Section 3.8.6 as well as all warranties provided hereunder) shall be in the English language. All dimensions and properties set forth herein, any Exhibit hereto and any Drawings and Specifications shall be specified in English or U.S. customary units unless otherwise approved by Owner or agreed with Owner as a normal practice with respect to LNG liquefaction facility or power plant design. Words not otherwise defined herein that have well-known and generally accepted technical or trade meanings are used herein in accordance with such recognized meanings in the United States of America.

 

2.2

PRECEDENCE OF AGREEMENT.

2.2.1 Each Party shall promptly notify the other in writing of any discovered conflict or inconsistency among any of the Exhibits or between any Exhibit and the body of this Agreement. In the event of any conflict between provisions of Sections of this Agreement, Drawings and Specifications and Exhibits, the following order of precedence for construction and interpretation shall apply unless the Parties otherwise agree:

(a) amendments, addenda or other modifications to this Agreement (including Change Orders) duly signed and issued after the Effective Date, with those of a later date having precedence over those of an earlier date;

 

24


 

(b) Sections of this Agreement;

(c) Exhibit R – Demonstration Tests and Performance Tests;

(d) Exhibit C – Contractor Rates;

(e) Exhibit B – Compensation;

(f) Exhibit D – Form of Project Schedule and Milestones;

(g) Exhibit A – Scope of Work; Applicable Codes and Standards;

(h) the remaining Exhibits to this Agreement; and

(i) Drawings and Specifications.

2.2.2 Subject to Section 2.2.1, in the event of a conflict among or within any of the levels set forth in Section 2.2.1, or between the documents described in Section 2.2.1 and any Agent For Contract, the more stringent provision shall prevail. Notwithstanding the above, the provisions of this Agreement, including all Exhibits, shall be wherever possible construed as complementary rather than conflicting. Silence regarding a matter shall not constitute a conflict with another component of the Agreement that specifically addresses such matter.

 

2.3

INTERPRETATION.

Unless the context otherwise requires:

2.3.1 Words singular and plural in number will be deemed to include the other and pronouns having a masculine or feminine gender will be deemed to include the other;

2.3.2 In respect of general oversight of the Work, review of any Drawings and Specifications, access to the Job Site and the Work and all other similar rights of Owner, the term Owner shall be deemed to include Owner’s Representative and its designated staff;

2.3.3 Any reference to this Agreement or any other contract or agreement entered into by Owner in respect of the Facility means such agreement and all schedules, exhibits and attachments thereto as may be amended, supplemented or otherwise modified and in effect from time to time, and shall include a reference to any document which amends, modifies or supplements it, or is entered into, made or given pursuant to or in accordance with its terms;

2.3.4 The terms “hereof,” “herein,” “hereby,” “hereto”, “hereunder” and similar words refer to this entire Agreement and not any particular Section, subsection or other subdivision of, or Exhibit, appendix or schedule to, this Agreement;

2.3.5 The terms “include” and “including” shall be construed as being at all times followed by the words “without limitation” or “but not limited to” unless the context specifically indicates otherwise;

 

25


 

2.3.6 The words “as more fully described in” or words and phrases of similar meaning are not intended to be, nor should be construed to limit in any way, the obligations of Contractor to provide Owner with a fully operational Facility pursuant to the terms hereof;

2.3.7 References to “Article,” “Section” or “Exhibit” are to this Agreement unless specified otherwise;

2.3.8 References herein to the terms, provisions or requirements of this Agreement shall be deemed to include, with respect to Contractor’s obligations to perform the Work, the terms, provisions and requirements of the Agent For Contracts (excluding payment obligations);

2.3.9 References to Contractor’s personnel include employees of a JV Member or its Affiliate assigned to the performance of the Work;

2.3.10 References to any law, statute, rule, regulation, notification or statutory provision (including Laws and Permits) shall be construed as a reference to the same as it may have been, or may from time to time be, amended, modified or re-enacted;

2.3.11 References to “jointly and severally” and “joint and several basis” shall, if construed under the laws of the State of Louisiana, be construed to describe a solidary obligation between the obligors to each obligee in solido;

2.3.12 Any reference to “KBR” in Attachment 4 or Attachment 5 of Exhibit A or Exhibit E shall be treated as a reference to “Contractor”;

2.3.13 References to any Person shall be construed as a reference to such Person’s successors and permitted assigns; and

2.3.14 The word “or” will have the inclusive meaning represented by the phrase “and/or”.

 

2.4

NEGOTIATION AND DOCUMENTATION OF THIS AGREEMENT.

Each of the Parties acknowledges and agrees that it has had the opportunity to have its legal counsel review this Agreement and participate in the joint negotiation and documentation of this Agreement, and that it is fully familiar with each of the provisions of this Agreement and the effect thereof. Accordingly, each Party irrevocably waives the benefit of any rule of construction that disfavors the drafting party and any defense related thereto.

 

3.

GENERAL PROVISIONS.

 

3.1

WORK TO BE PERFORMED.

3.1.1 Owner hereby engages and is relying upon Contractor to perform the Work in accordance with Exhibit A and the other requirements of this Agreement, and Contractor acknowledges such reliance and accepts such engagement. Owner and Contractor agree that Contractor’s obligation under this Agreement is to complete the Work so that the Facility successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the other provisions of this Agreement, including achieving Facility Mechanical Completion, Facility Substantial Completion, and Final Completion within the time and for the purpose designated herein, and to do and furnish everything incidental and necessary in connection therewith.

 

26


 

3.1.2 Prior to the execution of this Agreement, Contractor performed engineering, cost estimating and related services and developed, provided or verified all of the information that forms the scope of Work set forth in Exhibit A for the purpose of verifying that such information is adequate for, and Contractor represents and warrants to Owner that the scope of Work set forth in Exhibit A includes all the necessary obligations, including integration, as applicable, that are required to be performed by Contractor and Owner in order for, the Facility to operate in accordance with the terms of this Agreement and to satisfy the Applicable Codes and Standards, applicable Laws, Owner Standards and Permits and successfully pass the Performance Tests and meet or exceed the requirements set forth in Exhibit A. Items need not be specifically listed herein or in Exhibit A in order to be deemed to be items within the scope of the Work. It is understood that Contractor is better qualified to list exclusions than Owner is to list inclusions. Therefore, except for the supply of Owner Furnished Equipment and Materials and performance of the Owner Scope of Work, any item indicated herein, inferable therefrom, incidental thereto or required in accordance with any Law, Permits or Applicable Codes and Standards is to be considered as part of the Work. In addition, the Work includes all that should be included and all that would be customarily included within the general scope of the Work in order to complete the Facility (excluding the supply of Owner Furnished Equipment and Materials and performance of the Owner Scope of Work) according to the requirements of this Agreement, including Applicable Codes and Standards, applicable Laws, the requirements for the Performance Tests and the Permits. As a result, Contractor hereby waives any and all claims for an increase in the Target Price or an extension of any Applicable Deadline based, in whole or in part, upon an assertion that Contractor’s scope of Work in Exhibit A and as otherwise provided in the Exhibits was insufficient and did not include a certain license, technical assistance, engineering, assembly, construction, service, labor, material, equipment, operation or management beyond the scope of the Work when such license, technical assistance, engineering, assembly, construction, service, labor, material, equipment, operation or management is indicated in Exhibit A, this Agreement or any other Exhibit, the Drawings and Specifications or other instruments of service prepared by Contractor or a Subcontractor in connection with this Agreement reasonably inferable therefrom, incidental thereto, required in accordance with any Applicable Codes and Standards, applicable Law, Permits or otherwise necessary in order to complete the Facility in accordance with and subject to the requirements of this Agreement.

3.1.3 Time is of the essence with respect to Contractor’s achievement of each Applicable Deadline (other than the Final Completion Deadline).

 

3.2

GENERAL OVERSIGHT AND ACCESS.

3.2.1 Owner and the Owner Designees shall at all times have access to the Job Site and the Work wherever it is in preparation and progress and Contractor shall provide reasonable facilities for such access. Owner and the Owner Designees shall comply with the Contractor’s reasonable safety and access procedures. Each of Owner and the Owner Designees may (a) make inquiries of Contractor and visit the Job Site and Contractor’s work facilities and/or (b) maintain staff on the Job Site, in each case, to (i) familiarize itself with the progress and quality of the Work, (ii) determine if the Work is proceeding in accordance with this Agreement and (iii) witness and/or participate in Pre-Commissioning and Commissioning and any tests (including the Performance Tests) and inspections of the Materials and any other component of the Facility.

 

27


 

3.2.2 Subject to the limitations of the immediately following sentence, Owner Contractors and the Pipeline Contractor shall at all times have access to the entire Job Site wherever it is in preparation and progress, and Contractor shall provide reasonable facilities for such access. Owner Contractors and the Pipeline Contractor shall comply with the Contractor’s reasonable safety and access procedures for access to and when present on the Job Site.

 

3.3

JOB SITE CONDITIONS.

Except as otherwise provided herein, Contractor has had sufficient opportunity to review (a) information provided to it by Owner as set forth in Exhibit M and Exhibit N, (b) each Agent For Contract and (c) the information it has developed on its own (excluding sub-surface testing but including information learned by Contractor as result of activities performed by it under the Phase 1 Agreement), and it is sufficiently informed about the Job Site and surrounding locations, including all visible surface conditions, to the full extent it deems necessary for the performance of the Work and is familiar with and has satisfied itself with respect to (i) the nature and location of the Work and (ii) the general and local conditions with respect to (A) environment, (B) transportation (including to the Job Site and within the Job Site), (C) access, (D) the use, handling, storage and disposal of Hazardous Substances and other wastes brought to the Job Site by Contractor, any Subcontractor or any Agent For Contractor, (E) the use, handling and storage of Materials, (F) the availability and quality of temporary construction electric power, (G) the availability and surface condition of roads, climatic conditions and seasons (except to the extent any such climatic conditions constitutes a Force Majeure Event), (H) physical and environmental surface conditions at the Job Site and the surrounding area as a whole, (I) topography and ground surface conditions, (J) nature and quantity of surface materials to be encountered, (K) location of underground utilities existing prior to the Effective Date as disclosed to Contractor by Owner in writing in Exhibit M or Exhibit N or discovered by Contractor in its performance of the Phase 1 Agreement, (L) construction equipment, and other equipment, supplies and facilities needed prior to and during performance of Contractor’s obligations under this Agreement and (M) the availability and quality of workers, laborers and Subcontractors (the foregoing, collectively, the “Job Site Conditions”). Without prejudice to Article 12 with respect to Change Orders, Contractor expressly waives any claims for any increase in the Target Price or adjustment to the Project Schedule in connection with the Job Site Conditions.

 

3.4

OWNER NOT RESPONSIBLE FOR ACTS OF CONTRACTOR; CONTRACTOR NOT RESPONSIBLE FOR OWNER SCOPE OF WORK.

3.4.1 Other than with respect to means, methods, sequences, procedures and techniques of construction (for which Contractor shall have sole responsibility), Contractor will comply with reasonable instructions and requests of Owner or Owner’s Representative which are consistent with the Work, the requirements set forth in Exhibit A, and achievement of the Applicable Deadlines and successfully passing the Performance Tests; provided that Contractor will comply with reasonable technical instructions and requests of BH and UOP in connection with the unloading, transport, installation, connection, start-up, commissioning and operation of any Owner

 

28


 

Furnished Equipment and Materials supplied by BH and UOP. Owner will not be responsible for construction or manufacturing means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, and Owner will not be responsible for Contractor’s failure to carry out the Work in accordance with this Agreement, but this Section 3.4.1 shall not be deemed to otherwise modify Owner’s obligations with respect to Reimbursable Costs, Contractor’s G&A and Contractor’s Margin otherwise due and payable hereunder. Owner will not be responsible for the acts or omissions of Contractor, any Subcontractor, any Agent For Contractor or any of their agents or employees, or any other Persons performing any of the Work on behalf of Contractor or any Subcontractor or Agent For Contractor. No inspection, or failure to inspect, by Owner, Owner’s Representative or the Independent Engineer shall be a waiver of Contractor’s obligations, or be construed as approval or acceptance of the Work or any part thereof.

3.4.2 Except as set forth in Exhibit A, Contractor will not be responsible for construction or manufacturing means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Owner Scope of Work, and Contractor will not be responsible for Owner’s or any Owner Contractor’s failure to carry out the Owner Scope of Work, the supply or performance of the Owner Furnished Equipment and Materials (except to the extent expressly identified as part of the Work). Contractor will not be responsible for the acts or omissions of Owner, any Owner Contractor, or any of their agents or employees, or any other Persons performing any of the Owner Scope of Work.

 

3.5

EFFECT OF AND TIME FOR OWNER REVIEW OF DOCUMENTS.

Inspection, review or comment by Owner or the Independent Engineer (or the failure to do so) with respect to any Subcontract, Drawings and Specifications or other documents, or any other Work or services performed by Contractor or any Subcontractor or Agent For Contractor, shall not in any way affect or reduce any of the Contractor’s obligations to complete the Work so that the Facility successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the other provisions of this Agreement or in any way affect the Target Price. Contractor shall prepare Drawings and Specifications and submit them to Owner and the Independent Engineer at least thirty (30) days before the date on which the Work described in them is to be performed. Upon the written request of the Owner, Contractor shall provide to the Owner any information reasonably requested in connection with the Drawings and Specifications. Owner may, but is not obligated to, have the Independent Engineer review the Drawings and Specifications submitted by Contractor. Contractor shall discuss and answer any inquiries concerning the Drawings and Specifications with Owner or the Independent Engineer. Owner may reject or amend the Drawings and Specifications that are not in accordance with the requirements set forth in Exhibit A, Owner Standards and the other provisions of this Agreement by sending disapproval that states in reasonable detail the reason(s) for such disapproval or by sending revisions, in each case within fifteen (15) days from receipt of Drawings and Specifications.

 

3.6

CLAIMS UPON FAILURE OF MATERIAL.

In accepting the Work performed and Materials supplied, assembled or installed by Contractor, Owner assumes no responsibility for injury or claims resulting from (a) failure of such Work and Materials to comply with applicable Laws, Permits, safety requirements, Applicable

 

29


 

Codes and Standards and Owner Standards, (b) Contractor’s failure to unload, transport, integrate, install, connect, start-up, commission or operate all Owner Furnished Equipment and Materials in accordance with applicable Laws, Permits, safety requirements, Applicable Codes and Standards, Owner Standards, (provided that the Owner Standards, are consistent with applicable Laws, Permits, safety requirements, and Applicable Codes and Standards), (c) Defects or Deficiencies (other than Owner’s obligation hereunder to pay the Reimbursable Costs, Contractor’s G&A and Contractor’s Margin associated with Defects or Deficiencies) or (d) Corrective Work. Contractor’s performance of the Work shall include the provision of all necessary permanent safety devices in accordance with the terms hereof, Owner Standards and as required by Government Authority or applicable safety codes.

 

3.7

RESPONSIBILITIES OF OWNER.

Without limiting the requirements of any other provision of this Agreement, Owner shall:

3.7.1 furnish nonexclusive access to the Job Site to Contractor from and after the time of the issuance of the Notice to Proceed or, if expressly authorized in the Limited Notice to Proceed, the time of issuance of the Limited Notice to Proceed;

3.7.2 provide legal rights for ingress to and egress from the Job Site for Contractor and its Subcontractors for the performance of the Work and for the Owner Contractors and the Pipeline Contractor, consistent with Owner’s property rights with respect to the Job Site. During the progress of the Work, it will be necessary for Owner and Owner Contractors to work in or about the Job Site. In accordance with Section 3.2.2, Contractor shall afford such Owner Contractors reasonable access through and across the Job Site so as to not materially adversely interfere with or impede the progress and execution of work performed by such Owner Contractors in or about the Job Site. Contractor shall exercise good faith cooperation with the Owner Contractors and the Pipeline Contractor;

3.7.3 designate a single individual as Owner’s Representative to act as a single point of contact for Contractor, Owner Contractors and the Pipeline Contractor with respect to the prosecution of the Work. Any proposal, inspection, examination, testing, consent, approval or similar act by Owner’s Representative (including absence of disapproval) shall not relieve Contractor from any responsibility, including responsibility for its errors, omissions, discrepancies and non-compliance with the terms of this Agreement. Owner shall have the right to change the Owner’s Representative and/or modify his/her scope of responsibilities upon reasonable notice to Contractor. The Owner’s Representative shall be available at the Job Site and elsewhere, when reasonably required, at all reasonable times for consultation and, if absent, shall designate a suitable alternate to act as Owner’s Representative during such absence;

3.7.4 furnish personnel in accordance with Exhibit G for training, testing, operation and maintenance of the Facility, which personnel shall possess experience and education qualifications which in Owner’s determination are appropriate to permit achievement of the training objective;

3.7.5 with Contractor’s assistance, obtain or cause to be obtained in a timely manner the Permits listed in Exhibit L that are identified as Owner Permits (excluding for the avoidance of doubt the Permits set forth in Exhibit L that are identified as Contractor Permits) and any other

 

30


 

Permit required under applicable Law to be obtained by it in connection with the operation of the Facility. Upon receipt of any such Permit, Owner shall promptly provide a copy of such Permit to Contractor. In addition, Owner shall cooperate with Contractor in obtaining any Permit required to be obtained by Contractor in the performance of the Work. Contractor shall provide information reasonably requested by Owner to support Owner’s prosecution of any pending application listed in Exhibit L in respect to the Work and shall perform the Work in compliance with all of the terms and conditions of each of the foregoing Permits. Following Owner’s request, Contractor, on behalf of either Owner or itself, shall timely prepare and file all progress and other reports and any amendments as may be required by or in connection with said Permits and shall otherwise coordinate with any relevant Government Authority as requested by Owner;

3.7.6 obtain, provide and pay for the supply of (i) Feed Gas in accordance with Exhibit A and with the Feed Gas schedule prepared by Contractor in accordance with Section 3.8.11, (ii) [***] MW of electricity from the electrical utility grid, (iii) [***] gallons/day potable water as required for construction activities for the Work, (iv) improvement of the Job Site “fastlands” drainage system and pumping station to provide drainage of the Job Site during construction without standing water and (v) relocation of power and utility lines along Louisiana State Highway 23 in accordance with the Project Schedule;

3.7.7 (a) supply and, except as otherwise required in Exhibit A, deliver or cause to be delivered to the Job Site or a Satellite Facility, as applicable, all of the Owner Furnished Equipment and Materials to be incorporated into the Facility, (b) cause Owner Contractors to correct, repair, or replace all defects and deficiencies in Owner Furnished Equipment and Materials, (c) perform or cause to be performed the Owner Scope of Work, (d) with respect to Owner Furnished Equipment and Materials manufactured outside of the United States, cause such Owner Furnished Equipment and Materials to clear U.S. customs and Owner or Owner Contractor to be designated as the importer of record, in each case, in accordance with the requirements set forth in Exhibit A, applicable Law, Applicable Codes and Standards and the Permits; and (e) provide, or cause to be provided, relevant information and deliverables including, as applicable, system turnover packages from Owner Contractors that are obtainable under the Owner Contracts, as reasonably requested and to the extent not otherwise available to Contractor in the performance of its obligations hereunder;

3.7.8 during the period commencing on the LPS5 Substantial Completion Date and ending upon the Facility Substantial Completion Date, operate and maintain each LNG Production System Handover Package for which it has assumed care, custody and control hereunder in accordance with applicable Law, Permits, and operation and maintenance manuals provided by Contractor and Owner Contractors; and

3.7.9 obtain and maintain the insurance set forth in Section 26.3.

 

3.8

RESPONSIBILITIES OF CONTRACTOR.

Without limiting the requirements of any other provision of this Agreement, Contractor shall:

 

31


 

3.8.1 prosecute the Work continuously and diligently in accordance with Owner Standards, all applicable Laws, Permits, Applicable Codes and Standards and in accordance with the Project Schedule, using only qualified and competent personnel, and complete the Work so that the Facility successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the provisions of this Agreement;

3.8.2 ensure that all labor performing at the Job Site will be properly tooled, fully trained and qualified to safely perform the Work in accordance with applicable Law, Permits and Owner Standards;

3.8.3 perform and furnish the Work, including designing, engineering, procuring, manufacturing, packing and transporting, constructing, warranting, Pre-Commissioning, Commissioning, testing, training and directing of operating and maintenance personnel (including the personnel of Owner or its Affiliate) until Facility Substantial Completion, and guaranteeing performance of the Work in accordance with the terms hereof, so that the Facility (a) meets the requirements of all applicable Permits and applicable Laws, (b) meets the requirements of Owner’s property rights with respect to the Job Site identified in Exhibit N, (c) successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the provisions of this Agreement, (d) meets the requirements of the Applicable Codes and Standards, (e) is safe and adequate for conditions of loading, conveying, storing, metering, liquefying and delivering Feed Gas and LNG, (f) can be operated in a manner consistent with the staffing levels specified in Exhibit Q, (g) is capable of complying with the Laws (including Environmental Laws) issued by any Government Authority or other applicable entities set forth in Exhibit A and Exhibit L, and (h) comprises Materials which are new, are reasonable to maintain, have proven durability to withstand climatic conditions that could reasonably be expected to be experienced at the Job Site, are designed and manufactured in accordance with the requirements set forth in Exhibit A and are assembled and installed in accordance with manufacturer’s specifications and generally accepted standards for the design, manufacture, quality and assembly of such Materials;

3.8.4 obtain and maintain all Permits (including the Permits set forth in Exhibit L that are identified as Contractor Permits, but excluding the Permits set forth in Exhibit L that are identified as Owner Permits) and authorizations from any Government Authority, and administer all such Permits and authorizations required for (a) the design, engineering and construction of the Facility (or any portion thereof), (b) the procurement, handling, supply, shipment, transportation, installation, erection, direction of procurement and testing of the Materials, (c) the installation or integration of the Owner Furnished Equipment and Materials, and (d) the performance of all the Work. Contractor shall provide prompt assistance, information and documentation (including copies of any drawings and design documents) required or requested by Owner for the Work to enable Owner to obtain or modify, or cause to be obtained or modified, the Permits set forth in Exhibit L that are identified as Owner Permits. Contractor shall give Notice to Owner of all conflicts between the requirements set forth herein including Exhibit A and any Laws or Permits that come to the attention of Contractor or with the exercise of reasonable care should have come to the attention of Contractor. Contractor shall assist Owner in obtaining and maintaining all Permits that Owner must obtain pursuant to the terms hereof, including (i) providing information requested by Owner or requested or required by any Government Authority in the possession of, or reasonably obtainable by, Contractor, and (ii) identifying for Owner any Permits that Owner

 

32


 

has not obtained, but which Contractor has reason to believe, after due inquiry, must be obtained by Owner for the Contractor’s performance of the Work and/or Owner’s ownership or operation of the Facility. Contractor will provide Owner a copy of its Louisiana Contractor’s License and Louisiana Engineering Firm Registration prior to commencement of the Work;

3.8.5 take full responsibility for the adequacy, stability, cleanliness and safety of Contractor’s (and Subcontractors’ and Agent For Contractors’) Job Site operations, of Contractor’s (and Subcontractors’ and Agent For Contractors’) methods of construction and of the Work, irrespective of any approval or consent by Owner, Owner’s Representative or the Independent Engineer;

3.8.6 pay the Taxes, insurance and bank charges incurred by Contractor or any Subcontractor arising from the performance of its duties under this Agreement;

3.8.7 have joint responsibility with Owner for coordination with Government Authorities, test laboratories and any other Person necessary to demonstrate the Facility’s compliance with all Permits and Laws;

3.8.8 be responsible for fines and penalties to the extent they constitute Non-Reimbursable Costs;

3.8.9 except as provided in Section 3.7.6 or Exhibit V, obtain all consumables (including construction fuel, construction electricity, water and other utilities and the supply and fill of lubricants, resins, chemicals and the refill and top-off of such lubricants and chemicals following any Performance Tests and other consumables as provided in Exhibit V) necessary for Contractor’s performance of the Work, and Owner’s or its Affiliate’s execution of the Performance Tests, during the period from commencement of the Work through the LNG Production System Substantial Completion Date for the corresponding LNG Production System Handover Package for which Owner assumes care, custody, and control;

3.8.10 obtain all internet access, telephone and radio usage necessary for Contractor’s performance of the Work and for each Owner Contractor’s performance of its respective services and work during the period from commencement of the Work through the Facility Substantial Completion Date;

3.8.11 determine sufficiently in advance the quantities of Feed Gas, in MMBtu, that will be required for each Day on which Commissioning activities and the Performance Tests in respect of each LNG Production System will be conducted as provided in Exhibit A and Exhibit R;

3.8.12 Contractor shall perform such Work to integrate and tie-in the Facility with the Phase 1 Facility and otherwise perform the obligations set forth in Exhibit A to complete Owner’s 20 MTPA nameplate LNG export facility, comprised of the Facility and the Phase 1 Facility.

3.8.13 without limiting Owner’s obligations under Section 3.7.1, (a) until the earlier of the Facility Substantial Completion Date or termination of this Agreement, be responsible for the management of the Job Site (including (i) any construction routes between the road used to access the Job Site and the Job Site and within the Job Site boundaries, (ii) coordination of Subcontractors’ and Agent For Contractors’ activities and the management of all common areas

 

33


 

within the Job Site so as to optimize Contractor’s, Subcontractors’ and Agent For Contractors’ performance, (iii) provide any signs or directions which they may consider necessary for the guidance of its staff, labor and others and (iv) maintain the Job Site at all times free of waste material and rubbish), (b) upon the earlier of Final Completion or termination of this Agreement, clear the Job Site of temporary structures, surplus items (unless Owner requests such surplus items be left at the Job Site), construction equipment and tools, (c) until the earlier of the Facility Substantial Completion Date or termination of this Agreement, provide all reasonable and necessary safeguards, including fencing, signs, security services, fire protection and the like, for the health, safety, security and protection of the Job Site, the Work and the Facility and of all Persons and property related thereto, and (d) until the earlier of the Facility Substantial Completion Date or termination of this Agreement, keep unauthorized Persons off of the Job Site and reconstruct, repair or replace Materials or property of Contractor which may be stolen or damaged by vandalism;

3.8.14 take all reasonable steps to protect the environment and to limit damage and nuisance to people and property resulting from pollution, construction noise and other results of the performance of the Work, and ensure that the Work and any Releases, including construction air emissions, surface discharges and effluent, from its performance of the Work shall be in compliance with all applicable Permits, Applicable Codes and Standards and Laws;

3.8.15 within ninety (90) days following the earlier of (a) Facility Substantial Completion Date or (b) earlier termination of this Agreement as provided herein, (i) assist Owner in preparing an inventory of all Materials (wherever located), special tools, construction aids and all other Contractor or Subcontractor materials, equipment, supplies purchased and used in connection with the Work (the “Surplus Construction Materials”), and (ii) transfer, or cause the transfer, of possession and title to Owner of all Surplus Construction Materials that Owner elects to take possession of by Notice to Contractor;

3.8.16 provide reports, information and data as will be necessary for Owner to maintain segregated accounts of the Work for Owner’s records where required by Law or generally accepted accounting principles in the United States of America. Such segregation will include separate accounting for expenditures with respect to buildings, land improvements, engineering and project management, Materials, Feed Gas Interconnections, Permit costs and Taxes paid by Contractor;

3.8.17 if (a) a Dispute under this Agreement arises in connection with a default or termination of this Agreement, or Owner’s obligation to pay certain Taxes hereunder, (b) a Change Order payment is to be determined on a cost-plus basis (at the then applicable labor rates then set forth in Exhibit C) or (c) the Work is accelerated pursuant to Section 16.3.2, then, in each case, grant to Owner sufficient audit rights with respect to all documentation pertaining thereto. Owner shall have the right to choose an independent certified public accounting firm to act as auditor for such an audit and the reasonable cost of any audit will be borne by the Party whose position is not substantially supported by the results of such audit. Audit data shall not be released by such auditor to Persons other than Contractor, Owner, the Independent Engineer, the Lenders or their respective employees and agents in connection with any such audit and Owner and Contractor shall treat such audit data as confidential, but shall not be precluded from using such audit data in any legal or arbitration proceedings arising under this Agreement in relation with the Dispute or Change Order;

 

34


 

3.8.18 make available to Owner and Owner Contractors at all times during the term hereof sufficient storage areas and personnel at each Satellite Facility for the unloading, handling, preservation, storage, loading and transportation of all Owner Furnished Equipment and Materials delivered to such Satellite Facility by an Owner Contractor, and not take or omit to take, and cause its Affiliates not to take or omit to take, any action with respect to such Satellite Facility that would prevent, impede, delay or otherwise hinder Contractor’s performance of the Work in accordance with this Agreement;

3.8.19 arrange and/or ensure the complete handling of all equipment, machinery, Materials and spare parts required for the Work, including the inspection, expediting, shipping and transport, unloading, receiving, storage and payment of all Taxes incurred in connection therewith, and arrange for proper safe keeping, handling, preservation, storage, maintenance and transportation at, to or from a Satellite Facility or the Job Site, as applicable, for such equipment, machinery, Materials and spare parts;

3.8.20 coordinate customs expediting and clearance services and logistics at the Job Site with a qualified company selected by Owner and perform all administrative formalities in connection therewith, including obtaining all approvals, certificates, documents and licenses which may be pertinent and/or necessary for Contractor’s equipment, machinery, Materials and spare parts required for the Work, all in a timely manner;

3.8.21 transport from each Satellite Facility to the Job Site all Owner Furnished Equipment and Materials delivered to such Satellite Facility in accordance with the Project Schedule;

3.8.22 provide for all temporary construction materials, equipment, supplies and facilities necessary for the performance of the Work;

3.8.23 upon Notice from Owner, replace (a) any Subcontractor who fails to perform its Subcontract obligations and (b) replace any of Contractor’s personnel, and cause any Subcontractor to replace its personnel, performing the Work if (i) Owner believes that such personnel are negligently performing the Work or that such personnel are creating a risk to the health and/or safety of Persons or property or (ii) Owner believes that such personnel are otherwise not performing the Work in accordance with Owner Standards or are creating a risk to the timely completion of the Work in accordance with this Agreement;

3.8.24 provide all special tools, construction/Commissioning spare parts and supplies required for operation of the LNG Production System (excluding all special tools, construction/Commissioning spare parts and supplies provided as part of the Owner Furnished Equipment and Materials) until the LNG Production System Substantial Completion Date, at which time all special tools and other supplies required for the operation of the LNG Production System that are supplied by Contractor shall be transferred to Owner in accordance with Section 3.8.15;

3.8.25 use only the entrance(s) to the Job Site designated by Owner and applicable Permits for ingress and egress of all personnel and vehicles and for the delivery of all Materials;

 

35


 

3.8.26 provide such assistance as is reasonably requested by Owner in dealing with the Lenders, the Independent Engineer or any Government Authority in any and all matters relating to the Work and the Facility; provided that no review, approval or disapproval by the Independent Engineer shall serve to reduce or limit the liability of Contractor hereunder;

3.8.27 cooperate with Owner’s Representative and designee and the Independent Engineer in the review of design materials, the conduct of inspections and Commissioning, and in any other matters hereunder relating to the Work and respond promptly to inquiries from Owner;

3.8.28 provide all operating instructions, procedures, data and manuals, spare parts manuals, integrated and coordinated operation and maintenance manuals and training aids in accordance with the Drawings and Specifications;

3.8.29 train and certify the operating and maintenance personnel in accordance with Exhibit G;

3.8.30 perform the Pre-Commissioning and Commissioning and direct the operation and maintenance personnel (including the personnel of Owner or its Affiliate) during Pre-Commissioning, Commissioning and execution of the Performance Tests in full accordance with the written operating instructions, the operations and maintenance manuals and the safety procedures;

3.8.31 obtain Owner’s prior written approval (which approval may be withheld in Owner’s sole discretion and for any reason) of the text of any announcement, publication, photograph or other type of communication concerning the Work prior to the dissemination or release of same by Contractor or its Subcontractors;

3.8.32 subject to Owner’s prior approval, designate the Contractor’s Representative who will have full responsibility for the prosecution of the Work and full authority under the JV Agreement to act for Contractor in respect of this Agreement and act as a single point of contact with Owner, Owner Contractors and Pipeline Contractor in all matters on behalf of Contractor. Upon the reasonable written request of Owner, Contractor shall promptly replace the Contractor’s Representative. Subject to Section 5.2, Contractor shall not replace the Contractor’s Representative without the prior written consent of Owner, which consent shall not be unreasonably withheld. The Contractor’s Representative shall be available at the Job Site and elsewhere, when reasonably required, at all reasonable times for consultation and, if absent, shall designate a suitable alternate to act as the Contractor’s Representative during such absence;

3.8.33 during the performance of the Work, maintain continuously at the Job Site adequate management, supervisory, administrative, security, safety, quality and technical personnel, to ensure expeditious and competent handling of all matters related to the Work, according to its determination of the staffing required for this purpose and Exhibit Y. Contractor shall designate the Key Personnel as set forth in Exhibit K;

3.8.34 provide such data, reports, certifications, certified copies of organizational documents, resolutions, incumbency certificates, audited financial statements, opinions of counsel and other documents or assistance as may be (a) reasonably requested by Owner, the Lenders or Owner’s title insurance providers with respect to the Financing or otherwise requested by Owner in connection with the performance of this Agreement or (b) requested or required by any Government Authority with respect to any Permits or regulatory filings;

 

36


 

3.8.35 advise Owner of negotiations with Major Subcontractors concerning the availability of improved warranties or guarantees related to major items of Materials to be incorporated into the Facility;

3.8.36 (a) cooperate with and provide information reasonably requested by Owner to support Owner in performing, or causing the performance of, the Owner Scope of Work and the delivery of the Owner Furnished Equipment and Materials to the Job Site or a Satellite Facility, as applicable; (b) receive, transport and unload at the Job Site, or a Satellite Facility or a storage yard designated by Owner for transshipment to the Job Site, all Owner Furnished Equipment and Materials; (c) perform the construction management services relating to the scheduling and coordination of the work and services performed by the Owner Contractors under the Owner Contracts and the administration and reporting to Owner of the performance by each Owner Contractor of its obligations of the relevant Owner Contract(s); and (d) install and integrate the Owner Furnished Equipment and Materials into the Facility;

3.8.37 coordinate and perform the applicable portion of the Work under the oversight and direction of BH personnel that are present at the Job Site or a Satellite Facility pursuant to the Field Services Agreement;

3.8.38 maintain qualified personnel on the Job Site to consult with Owner regarding the operation and maintenance of the Facility (a) during Pre-Commissioning, Commissioning, start-up and testing of each LNG Production System and the Facility, (b) until successful completion of the training program required by Article 14 and (c) in accordance with the Warranty procedures set forth in Article 20 during the Warranty Period (which does not require Contractor to maintain personnel on the Job Site);

3.8.39 comply with the Warranty procedures set forth in Article 20;

3.8.40 in accordance with Article 39, cooperate with Owner in obtaining suitable Financing in accordance with the Lenders’ requirements;

3.8.41 provide complete Deliverables and follow them during the performance of the Work;

3.8.42 prepare and keep up-to-date on a daily basis a complete set of red-lined “as-built” records of the execution of the Work, showing the “as-built” locations, sizes and details of the Work as executed, with cross references to relevant specifications and data sheets, which records shall be kept on the Job Site and shall be made available to Owner upon request;

3.8.43 prepare and submit to Owner “as-built” drawings (in accordance with Exhibit J) of the Work showing the process-related portions of the Work as executed. The “as-built” drawings shall be provided in their native file format, red-lined as the Work proceeds, and shall be submitted at least monthly (and more frequently as requested by Owner) to Owner for its inspection;

3.8.44 submit to Owner, within sixty (60) Days following the Facility Substantial Completion Date or upon termination of this Agreement, five (5) electronic files in a format designated by Owner, one (1) full-size original copy and six (6) printed copies of the relevant final “as-built drawings” (in accordance with Exhibit J) and any further construction documents relating to the Work reasonably requested by Owner, all prepared in accordance with this Agreement;

 

37


 

3.8.45 in accordance with Article 9, submit to Owner the applicable Performance Security;

3.8.46 refrain from bringing, and not permit or allow any Subcontractor, Agent For Contractor or other Person (other than an Owner Contractor acting in accordance with the relevant Owner Contract or the Pipeline Contractor) to bring, any Hazardous Substances on the Job Site and bear all responsibility and liability for such materials brought to the Job Site by Contractor, its Subcontractors or any Agent For Contractors; provided, however, that Contractor, Subcontractors and Agent For Contractors may bring onto the Job Site such Hazardous Substances as are necessary to perform the Work so long as the same is done in compliance with applicable Laws, Permits, and Applicable Codes and Standards, and Contractor shall remain responsible and liable for all such Hazardous Substances. Contractor shall maintain an updated record and current inventory of all Hazardous Substances brought onto the Job Site or used by Contractor or any Subcontractors or Agent For Contractors in connection with the performance of the Work, which records shall identify types, quantities, location of storage, use and final disposition of such Hazardous Substances, and shall promptly make such file available to Owner at the Job Site upon preparation and any updates. If Contractor, any of its Subcontractors, or any Agent For Contractors cause or permit a Release of any Hazardous Substances brought to the Job Site by Contractor, its Subcontractors or Agent For Contractors on, at, under or from the Job Site, Contractor shall, at its sole cost and expense: (a) immediately notify Owner in writing; (b) comply with all applicable Laws, Permits and Applicable Codes and Standards and take all necessary steps to protect human health and the environment, and shall not exacerbate such condition; and (c) diligently proceed to take all necessary actions to clean up fully any contamination or impacts resulting therefrom. If Contractor, any of its Subcontractors, or any Agent For Contractor encounter a Release of any Hazardous Substances on, at, under or from the Job Site that is not caused or permitted by any of them or any Pre-Existing Hazardous Substances, Contractor shall: (a) immediately notify Owner in writing; (b) comply with all applicable Laws, Permits and Applicable Codes and Standards and take all necessary steps to protect human health and the environment, and shall not exacerbate such condition; and (c) diligently proceed to take all necessary actions to assist Owner’s efforts to clean up fully any contamination or impacts resulting therefrom;

3.8.47 during the performance of the Work, maintain an office at the Job Site, in a temporary or permanent structure that shall be subject to the approval of Owner, which shall serve as the offices for Contractor, Owner and Owner Contractors, and upon completion of the Work, leave such offices, which shall remain the property of Owner, in a clean condition satisfactory to Owner;

3.8.48 cooperate and cause the Subcontractors and Agent For Contractors to cooperate with Owner, Owner Contractors, the Pipeline Contractor and other unrelated contractors who may be working at or near the Job Site in accordance with the Project Schedule in order to assure that neither Contractor nor any of the Subcontractors nor any of the Agent For Contractors unreasonably hinders or increases or makes more difficult the work being done by or on behalf of Owner, the operation of the Facility and other unrelated contractors at or near the Job Site;

 

38


 

3.8.49 use reasonable efforts, and cause the Subcontractors and Agent For Contractors to use their reasonable efforts, to assist Owner in creating, assessing and carrying out programs which shall, during all phases of the Work, minimize the impacts on the host community caused by completion of the Work;

3.8.50 pay all Subcontractors in a timely fashion in accordance with the respective Subcontracts and provide Owner with Notice of any material dispute regarding the Work that is pending or threatened, which Notice shall detail the dispute, the parties involved and identify any Subcontractors that Contractor intends to withhold payment from and the amount to be withheld;

3.8.51 obtain and maintain the insurance set forth in Section 26.2. Contractor shall (a) cooperate with Owner so that Owner may obtain and maintain the insurance set forth in Section 26.3, including providing any information reasonably required by insurance carriers providing such insurance, and (b) comply with the requirements of the insurance policies provided by Owner pursuant to Section 26.3, including providing information necessary to substantiate any claims filed under such policies;

3.8.52 in accordance with Article 23, ensure that all agreements, guarantees, warranties, delivery schedules and performance requirements with Subcontractors comply with the requirements of this Agreement;

3.8.53 in accordance with Article 40, comply with the requirements of the Anti-Corruption Laws and Export Controls;

3.8.54 in accordance with Section 3.9, obtain recommendations for spare parts for the operation and maintenance of the Facility and, if requested by Owner, procure and deliver the Spare Parts to the Job Site;

3.8.55 as applicable comply in all respects with the requirements, prohibitions, and other obligations applicable to a general contractor under Louisiana’s Private Works Act, Louisiana Revised Statute 9:4801, et seq.;

3.8.56 as applicable after the issuance of the Notice to Proceed (or, if required by Law in connection with the performance of the scope under any Limited Notice to Proceed, the Limited Notice to Proceed) properly and timely file written notice of contract (the “Notice of Contract”), together with performance and payment bonds attached, if required, and a “no work” affidavit satisfying the requirements of Louisiana Revised Statute 9:4820.C. for registry with the recorder of mortgages of the parish in which the Work is to be performed. Preparation and filing of the notice of contract and bonds shall comply with Louisiana’s Private Works Act, La. R.S. 9:4801, et seq.;

3.8.57 as applicable upon Final Completion, file a notice of termination for registry with the recorder of mortgages for Plaquemines Parish, referencing the Notice of Contract, and satisfying the requirements of Louisiana Revised Statute 9:4822.E.;

3.8.58 as applicable as a condition precedent to final payment by Owner hereunder, supply to Company a Clear Lien and Privilege Certificate for the Facility from the recorder of mortgages for Plaquemines Parish, which certificate is dated after the expiration of the period during which Subcontractors and suppliers may file valid claims or liens pursuant to Louisiana’s Private Works Act, LA. R.S. 9:4801, et seq.; and

 

39


 

3.8.59 as applicable as a condition precedent to final payment by Owner hereunder, at Owner’s request, Contractor shall file, or concur with the filing of, a request for cancellation of the Notice of Contract pursuant to Louisiana Revised Statute 9:4832.A.

 

3.9

SPARE PARTS.

3.9.1 Promptly following Contractor’s issuance of a Subcontract or the execution of an Agent For Contract, Contractor shall deliver to Owner a detailed list (that shall include pricing information) of all Subcontractor, Agent For Contractor and Contractor-recommended capital spare parts, other spare parts and special tools necessary for operating and maintaining the Facility (excluding all spare parts and special tools supplied as part of the Owner Furnished Equipment and Materials), including components and systems of the Facility (collectively, “Spare Parts”), following each LNG Production System Substantial Completion Date and the Facility Substantial Completion Date. One hundred eighty (180) Days prior to LPS5 Substantial Completion Date, Owner shall specify in writing which items on the list it wishes Contractor to purchase and whether such items are requested to be delivered to the Job Site prior to LNG Production System Substantial Completion for an LNG Production System, Facility Substantial Completion or Final Completion, as applicable. For those Spare Parts Owner directs Contractor to purchase, Contractor shall purchase such Spare Parts on the best available commercially reasonable terms (including all rebates and discounts). In addition to ordering and purchasing the Spare Parts as provided above, Contractor shall receive, inspect, deliver to storage and take all other reasonable actions for the storage and maintenance of the Spare Parts until the Final Completion Date.

3.9.2 Contractor shall properly store and categorize all spare parts provided pursuant to Section 3.9.1 in order to preserve such spare parts and prevent corrosion, and shall create and maintain a computerized inventory of all such spare parts. Contractor shall submit the inventory control system to Owner for review and such inventory control system shall be approved by Owner prior to its implementation. Contractor shall cause the inventory control system to be transferred to Owner’s computer system at the Facility prior to the LPS5 LNG Production System Substantial Completion Date. Any spare parts purchased by Owner that are present at the Job Site prior to Owner’s assumption of the care, custody and control of the Facility pursuant to Section 18.1.3 and during the Warranty Period may be reasonably used by Contractor following written permission by Owner; provided, however, that Contractor shall be required to replace such spare part with an identical new replacement on an expedited basis.

 

3.10

PROCUREMENT.

3.10.1 Within [***] Days after the date of issuance of the initial Limited Notice to Proceed, Contractor shall provide Owner with an estimated schedule of the planned air, marine and land shipments for which Contractor is responsible, identifying (a) equipment estimated to be essential to the Critical Path, (b) the equipment and values to be contained in each shipment, and (c) other specific information reasonably required by insurance underwriters (including the vessel and/or vehicle identification, the itinerary and schedule along with scheduled shipping dates from each Satellite Facility or Contractor’s, a Subcontractor’s, an Agent For Contractor’s or their

 

40


 

supplier’s warehouse) (collectively, the “Shipping Information”). Thereafter, in order for Owner to secure insurance for each marine, air and land shipment made by Contractor, Contractor shall provide monthly updates to Owner and Owner’s designated cargo insurer of any changes to the Shipping Information. Contractor shall not permit any shipment to be made until such Notice is timely given to Owner. Shipping delays incurred by Contractor or any Subcontractor or Agent For Contractor as the result of delays in securing cargo insurance to the extent due to Contractor’s failure to supply such Notice on a timely basis shall not be the basis for an Owner Caused Delay. Contractor shall ensure that all shipments of cargo by Contractor or any Subcontractors or Agent For Contractors comply with requirements related thereto of such insurance providers.

3.10.2 Each shipment manifest of Contractor and any Subcontractor or Agent For Contractor will be prepared in a format consistent with the reasonable requirements of Owner.

 

4.

COMMENCEMENT OF THE WORK.

 

4.1

NOTICE TO PROCEED.

4.1.1 Owner may issue to Contractor a Notice in the form attached hereto as Exhibit F-13 (the “Notice to Proceed”) specifying the date for full commencement of the Work (the “Notice to Proceed Date”), which date shall not be prior to either the date that Contractor receives the Notice to Proceed and the advance payment of a mutually agreeable fixed amount that is specified in the Notice to Proceed to be due and payable upon the issuance of the Notice to Proceed. One hundred percent (100%) of such advance payment shall be credited as an offset against Reimbursable Costs, Contractor’s G&A and Contractor’s Margin owed by Owner to Contractor from and after the Notice to Proceed Date, until such advance payment is reduced to zero. Subject to any Limited Notice to Proceed, Contractor shall commence the Work only after the Notice to Proceed Date specified in the Notice to Proceed and thereafter diligently pursue the Work, assigning to it a priority that will ensure LNG Production System Substantial Completion of each LNG Production System on or before the applicable LNG Production System Substantial Completion Deadline, Facility Substantial Completion on or before the Facility Substantial Completion Deadline and Final Completion on or before the Final Completion Deadline. Contractor shall proceed with the performance of the Work in accordance with the Project Schedule; provided, however, that any failure of Contractor to pursue the Work in accordance with the Project Schedule shall not relieve Contractor of any liability hereunder.

4.1.2 Prior to the issuance of the Notice to Proceed, Owner intends to obtain sufficient funds from one or more Lenders to fulfill its payment obligations under this Agreement. Owner shall not issue the Notice to Proceed, and therefore shall have no payment obligations under this Agreement, unless and until the date on which it has obtained written and binding commitments in respect of such funds.

4.1.3 On or prior to Owner’s issuance of the Notice to Proceed pursuant to this Section 4.1 or within thirty (30) days after the Effective Date, whichever is later, Contractor shall provide the Performance and Payment Bonds to Owner as required pursuant to Article 9.

 

41


 

4.1.4 If prior to [***] (or such other date as the Parties may mutually agree in writing), Owner has not (a) issued the Notice to Proceed pursuant to this Section 4.1 or (b) issued a Change Order to Contractor for an equitable extension of the Project Schedule in accordance with Exhibit D, then either Party shall be permitted to terminate this Agreement by delivery of written notice thereof to the other Party.

 

4.2

LIMITED NOTICES TO PROCEED.

Prior to the issuance of the Notice to Proceed, Owner shall have the right to issue one or more limited notices to proceed directing Contractor to commence and complete any portion of the Work specified in any such limited notice to proceed and subject to the terms of this Agreement substantially in the form attached hereto as Exhibit F-8 (each, a “Limited Notice to Proceed”), except as otherwise agreed by Owner and Contractor. All activities required to be performed thereunder shall be done in accordance with the requirements for the Work hereunder. Contractor shall not be required to commence performance of the Work described in a Limited Notice to Proceed until it has received payment of a mutually agreeable fixed amount that is specified in the Limited Notice to Proceed to be due and payable upon the issuance of the Limited Notice to Proceed. One hundred percent (100%) of such payment shall be credited as an offset against subsequent Reimbursable Costs, Contractor’s G&A and Contractor’s Margin owed by Owner to Contractor, as applicable. Upon issuance of the Notice to Proceed, all such performance of the Work under a Limited Notice to Proceed shall constitute Work done pursuant to this Agreement.

 

5.

PERSONNEL AND QUALIFICATIONS.

 

5.1

GENERAL.

5.1.1 Contractor represents to Owner that it, its designers and its design Subcontractors have the experience and capability necessary for the design and performance of the Work. Contractor undertakes that its personnel and design Subcontractors shall be available to attend discussions with Owner and the Independent Engineer at all times at the Job Site or other mutually agreed locations during the performance of the Contractor’s obligations hereunder.

5.1.2 Contractor, all Subcontractors and all personnel used by Contractor and Subcontractors in the performance of the Work shall be qualified by training, licenses or certifications, as required, and experienced to perform their assigned tasks. Contractor shall not use in the performance of the Work any personnel reasonably deemed by Owner to be incompetent, careless, unqualified to perform the work assigned to them, unsafe, creating an unsafe work environment or interfering with the completion of the Work. Notwithstanding the foregoing, Owner shall have no liability and Contractor agrees to release indemnify, defend and hold harmless each Owner Indemnitee from and against any and all Losses, of whatsoever kind or nature, which may directly or indirectly arise or result from Contractor or any Subcontractor terminating the employment of or removing from the Work any such employee who fails to meet the foregoing requirements following a request by Owner to have such employee removed from the Work.

5.1.3 Contractor shall maintain labor relations in such a manner that, so far as reasonably practicable, there is harmony among workers. Contractor and the Subcontractors shall conduct their labor relations in accordance with the recognized prevailing local area practices, applicable Law, Permits, Applicable Codes and Standards and Owner Standards.

 

42


 

5.2

KEY PERSONNEL.

The Contractor’s organizational structure for the performance of the Work is provided in Exhibit K. Prior to the commencement of the Work, the Key Personnel shall hold the positions indicated in Exhibit K. Contractor acknowledges and agrees that the continuity of Key Personnel in connection with the Work is a material requirement of this Agreement and that the replacement of any Key Personnel will be detrimental to Owner and the overall quality of the Work. The Key Personnel will be engaged full-time and exclusively in the prosecution of the Work continuously until their role is completed, unless prior release is approved or directed by Owner; provided however, Key Personnel may be removed by Contractor without Owner’s consent for (a) termination of a Key Personnel’s employment with the Contractor or its Affiliates, or (b) a Key Personnel dying, retiring, resigning, or becoming seriously ill, or a serious illness or death in the family of a Key Personnel. Revisions to the organizational structure of Key Personnel shall be subject to Owner’s prior approval, and replacement of, or additions to, such Key Personnel shall only be made with persons having qualifications equal to or better than those replaced or added to, and shall be similarly subject to Owner’s prior approval. All requests for the substitution of Key Personnel shall include a detailed explanation and reason for the request and the resumes of professional education and experience for a minimum of two (2) candidates of suitable qualifications and experience. Owner shall respond within ten (10) days of receiving the resumes with its written approval or detailed comments as to why approval is not granted. Should Owner approve of the replacement of a Key Personnel, Contractor shall allow for an overlap of a minimum of two (2) weeks during which both the Key Personnel to be replaced and the Owner-approved new Key Personnel shall work together full time. Owner may if it is concerned with the performance thereof request in writing the removal of, and Contractor shall promptly remove and replace, any Key Personnel. Contractor agrees that, notwithstanding its other business commitments, it will give the Work a priority and commit sufficient resources to the Work that will enable Contractor to perform its obligations under this Agreement.

 

6.

PRICE AND PAYMENT.

 

6.1

TARGET PRICE.

6.1.1 The “Target Price” is an amount equal to [***], the principal components of which are more fully described in Exhibit B-2, as may be adjusted from time to time pursuant to a Change Order, to be paid pursuant to Section 6.3.

6.1.2 Contractor has satisfied itself as to (i) the correctness and sufficiency of the Target Price for the purposes of the waiver of any increase as described in Section 3.1.2 and (ii) the sufficiency of the Target Price for giving effect to the provisions of Article 8. The Target Price includes the estimated costs for the Materials, labor, transportation, services and Intellectual Property rights forming part of the Reimbursable Work and, including the costs of Materials,

transportation and storage of Materials and all Taxes other than sales and use taxes, duties and tariffs for which Contractor is responsible hereunder, the cost to Contractor to provide the Performance Security, and Contractor’s estimated cost for repair or replacement of all Defects and Deficiencies and other corrective Work prior to the commencement of the Warranty Period, including as described in Exhibit B.

 

43


 

6.1.3 For the avoidance of doubt, the Parties agree that all items listed in Exhibit A – Attachment 5 (the “Closed Cost Items”) are included in the Work, the Project Schedule and the Target Price, and are subject to all other requirements of this Agreement. The Parties also acknowledge that Contractor shall neither submit nor be granted a Change Order to adjust the Target Price and/or Project Schedule for any Work related to the Closed Cost Items.

 

6.2

NOT USED.

 

6.3

PAYMENT.

6.3.1 Not later than the 15th day of each Month N, Contractor shall submit to Owner for its approval a Request for Payment (simultaneously sending copies to the Independent Engineer, as Owner may direct), which shall set forth: (a) a reasonable good faith estimate of (i) the Reimbursable Work activities that will be performed during the second month (“Month N+2”) immediately following such Month N and (ii) the Direct Costs and Contractor’s G&A associated with such Reimbursable Work activities (the sum of clauses (i) and (ii) being referred to herein as an “Estimated Monthly Amount”) less, in the case of the Initial Request for Payment, the amount of the advance payment described in Section 4.1.1; (b) except for the Initial Request for Payment, the amount owed to Contractor in respect of the Reimbursable Work performed during the preceding month(s), together with Contractor’s G&A and Contractor’s Margin associated with such Reimbursable Work, that has not been paid to Contractor during such preceding month(s), as applicable; (c) except for the Initial Request for Payment, the amount by which the aggregate amount of Estimated Monthly Amounts paid to Contractor during the preceding month(s) exceeds the actual Direct Costs incurred by Contractor in the performance of the Reimbursable Work during the preceding month(s), calculated as of the last day of the month immediately preceding such month, and the Contractor’s G&A associated with such Direct Costs payable by Owner in respect of such Reimbursable Work; (d) without duplication of amounts described in clauses (a) through (c) above, any other amounts that may be due and owing from Owner to Contractor or from Contractor to Owner pursuant to any other provision of this Agreement, as well as Contractor’s Margin for any and all Margin Milestones achieved by Contractor during or prior to Month N as per the schedule defined in Appendix 1 of Exhibit D; and (e) all information and documentation required by Section 6.3.3.

6.3.2 Owner shall, with respect to the Initial Request for Payment, make payment of the net amount specified in such Request for Payment within fifteen (15) Business Days of its receipt of such Request for Payment and with respect to each subsequent Request for Payment in accordance with Section 6.6.

6.3.3 Each Request for Payment submitted by Contractor pursuant to Section 6.3.1 will be accompanied by: (a) a certificate of release and waiver of liens (other than Permitted Liens) from Contractor in the form attached hereto as Exhibit F-1; (b) a Payment Status Affidavit from Contractor in the form attached hereto as Exhibit F-15; (c) certificates of release and waiver of liens (other than Permitted Liens) from each Major Subcontractor providing Materials or services described in the Request for Payment in the form attached hereto as Exhibit F-2; (d) a Payment Status Affidavit from each Major Subcontractor in the form attached hereto as Exhibit F-16; (e) a Monthly Progress Report pursuant to Section 13.3; (f) a report of Defects and Deficiencies pursuant to Section 10.2.1; (g) supporting documentation evidencing the Reimbursable Costs and

 

44


 

Contractor’s G&A that are defined in Exhibit B; (h) the aggregate accrued amount of the Contractor’s Margin (with supporting calculations) of which payment is requested in respect of the Margin Milestone(s) that have occurred in the previous month; and (i) any other information that Owner, the Lenders or the Independent Engineer may reasonably request (provided Contractor is given a reasonable period of time (in any case, not less than ten (10) Days) to satisfy such request prior to Contractor’s submission of a Request for Payment). Contractor shall itemize Taxes (which are Reimbursable Costs) by category and cost component, including Louisiana state and local sales/use tax and any other sales/use tax that Contractor may be responsible for collecting from Owner (by state and taxing jurisdictions), import duties, and sales tax of other states (by other state). Contractor shall only include Direct Costs in a Request for Payment in accordance with the rates and other provisions set forth in Exhibit B-1 and Exhibit C.

6.3.4 Amounts (a) owed by Owner to Contractor and (b) owed by Contractor to Owner shall, to the extent not paid when due pursuant to the terms hereof, accrue interest at the Late Payment Rate from the date payment thereof was due until the date of payment thereof in full (together with all accrued interest).

6.3.5 In no event shall the payment of any amount by Owner to Contractor constitute an acceptance of any Work, and Owner’s acceptance of the Work shall not relieve Contractor of any of its obligations hereunder.

6.3.6 Notwithstanding anything to the contrary contained herein, failure by Owner to pay any amount in dispute until resolution of such dispute in accordance with this Agreement shall not alleviate, diminish, or modify in any respect Contractor’s obligations to perform hereunder.

6.3.7 Notwithstanding anything to the contrary contained herein, except as expressly set forth in a Limited Notice to Proceed, Contractor shall not be obligated to perform any further Work and Owner shall not be obligated to make any further payment hereunder until after the Financial Closing Date has occurred.

6.3.8 Contractor’s Margin shall only be payable as and when required pursuant to, and in the amounts specified in, the Margin Milestones. For the avoidance of doubt, no Contractor’s Margin in respect of any Margin Milestone shall be due and payable by Owner until such Margin Milestone has been achieved by Contractor, such achievement being confirmed by a Certificate of Achievement to be provided by Contractor together with the relevant Request for Payment. For the avoidance of doubt, no Margin Milestone shall be due and payable by Owner until such Margin Milestone has been achieved by Contractor.

6.3.9 All Non-Reimbursable Costs shall be borne exclusively by Contractor. Contractor shall not include any Non-Reimbursable Costs in a Request for Payment or otherwise seek reimbursement from Owner of any Non-Reimbursable Costs.

6.3.10 Owner shall have the right to audit all documentation pertaining to each Request for Payment on reasonable prior notice to Contractor and during normal business hours in order to confirm the accuracy and completeness of such Request for Payment.

 

45


 

6.3.11 The Parties acknowledge that the amount of Contractor’s Margin payable by Owner in respect of each Margin Milestone is calculated based on a percentage of the then applicable Base Target Price. The following methodology will be applied with respect to any (i) adjustment to the Base Target Price after the Effective Date, (ii) instance where the aggregate amount of Direct Costs (other than Tax Costs) and Agent for Contract Costs (other than Tax Costs) incurred in the performance of the Reimbursable Work exceeds the then applicable Base Target Price or (iii) early termination of this Agreement:

(a) Upon an increase to the Base Target Price, the amount payable for each Margin Milestone in respect of which Contractor’s Margin has previously been paid shall be automatically increased to reflect the applicable milestone percentage of the amount of the increase to the Base Target Price, and the positive difference between such increased amount payable and the amount previously paid shall be invoiced by Contractor to Owner in the next following Request for Payment; provided, however, that any portion of the increase to the Base Target Price that has previously been invoiced to Owner and paid in accordance with clause (c) of this Section 6.3.11 shall be excluded from the application of this clause (a).

(b) Upon a decrease to the Base Target Price, the amount payable for each Margin Milestone in respect of which Contractor’s Margin has previously been paid shall be automatically decreased to reflect the applicable milestone percentage of the amount of the decrease to the Base Target Price, and the positive difference between the amount previously paid and such decreased amount payable shall be applied as a credit to Owner in the next following Request for Payment.

(c) If at any time the aggregate amount of Direct Costs and Agent for Contract Costs incurred in the performance of Reimbursable Work exceeds the then applicable Base Target Price, payments of Contractor’s Margin for all Margin Milestones shall be recalculated by applying such aggregate amount in place of the Base Target Price in the definition of “Contractor’s Margin”, and the positive difference resulting from such recalculation shall, with respect to each Margin Milestone in respect of which Contractor’s Margin has previously been paid, be invoiced by Contractor to Owner in the next following Request for Payment; provided, however, that the Contractor’s Margin shall not be adjusted pursuant to this clause (c) more than once every ninety (90) days.

(d) If this Agreement is terminated pursuant to and in accordance with Article 31, the amount of Contractor’s Margin owed to Contractor upon such termination shall be calculated on the basis of all Direct Costs (other than Tax Costs) and Agent for Contract Costs (other than Tax Costs) incurred in the performance of Reimbursable Work prior to the date of such termination rather than the Appendix 1 of Exhibit D Margin Milestone payment schedule. If the amount of Contractor’s Margin calculated pursuant to the preceding sentence is greater or less than the aggregate amount of Contractor’s Margin paid to Contractor prior to the date of such termination, the difference shall be paid to Contractor or Owner, respectively.

 

46


 

6.4

ENCUMBRANCES.

6.4.1 Contractor covenants and agrees that, with the sole exceptions of (a) an arbitral or Government Authority’s decision in Contractor’s favor and (b) Permitted Liens, no mechanics’ liens, similar liens or any encumbrances whatsoever shall be filed or maintained by Contractor, any Subcontractor, any Agent For Contractor, or worker or other Person acting, directly or indirectly, through or under Contractor or any Subcontractor or Agent For Contractor, against the Job Site, the Facility (or any portion thereof), any Materials or Owner Furnished Equipment and Materials, any land or improvements pertinent thereto, for or on account of any Work done or to be done or Materials furnished or to be furnished hereunder (the foregoing types of liens, regardless of who files them, collectively, the “Indemnified Liens”). Any lien or encumbrance filed by Contractor shall be limited in scope to secure payment by Owner of the amount at issue in any applicable dispute resolution proceeding. Upon Owner’s payment of such amount, Contractor shall immediately, and in any event within seven (7) Days of such payment, effect release (and certify thereto) of any such lien or encumbrance. For the avoidance of doubt, if a dispute resolution proceeding is brought within the applicable statute of limitations, but the outcome of such proceeding is not determined until after the statute of limitations has expired, the Parties agree to waive the statute of limitations in order to effect the outcome of such dispute resolution proceeding.

6.4.2 If Contractor fails to satisfy the obligation set forth in Section 6.4.1 within thirty (30) days, Contractor agrees, to the fullest extent permitted by Law, to indemnify and hold harmless each of the Owner Indemnitees and the Owner’s title insurers against any and all Losses associated with any Indemnified Lien or any lien on an asset of Owner, and Owner shall have the right to (a) consider the amount of the lien or encumbrance as presumptively correct, (b) withhold from any payment to Contractor then due, or thereafter to become due (including the Final Request For Payment), an amount sufficient to completely indemnify Owner Indemnitees against such lien or encumbrance, (c) pay the amount of such lien or encumbrance and pursue recovery actions against Contractor and (d) retain out of the amount withheld an amount sufficient to compensate Owner for its expenses (including actual attorney’s fees) in the matter.

6.4.3 Contractor hereby subordinates any mechanics’ and materialmen’s liens or other claims or encumbrances that may be brought by Contractor against any or all of the Work, the Facility, or the Job Site to any liens granted in favor of the Lenders, whether such lien in favor of the Lenders is created, attached or perfected prior to or after any such liens, claims or encumbrances, and shall use commercially reasonable efforts to require its Subcontractors to similarly subordinate their lien, claim and encumbrance rights. Contractor agrees to comply with reasonable requests of Owner for supporting documentation required by the Lenders in connection with such subordination, including any necessary lien subordination and other agreements and the filing of necessary documentation to effectuate such subordination. Nothing in this Section 6.4.3 shall be construed as a limitation on or waiver by Contractor of any of its rights under applicable Law to file a lien or claim or otherwise encumber the Facility as security for any undisputed payments owed to it by Owner hereunder which are past due; provided that such lien, claim or encumbrance shall be subordinate to any liens granted in favor of the Lenders.

 

6.5

DEFICIENT REQUESTS FOR PAYMENT.

Should Owner and the Lenders believe any Request for Payment is non-conforming (by being incomplete or inaccurate or by not otherwise satisfying the requirements for a Request for Payment hereunder), Owner shall have the right, in its sole discretion, to (a) request additional information with respect to such non-conforming Request for Payment or (b) reject the non-conforming portion of a Request for Payment, but pay the undisputed portion in accordance with

 

47


 

this Agreement. It is understood and agreed by the Parties that any Request for Payment which is non-conforming, to the extent of such non-conformance, shall not constitute a valid and proper Request for Payment, and Owner shall not be obligated to make payment of any disputed amounts related to such non-conformance until Contractor revises the Request for Payment or submits a Request for Payment in proper form.

 

6.6

OWNER PAYMENT OBLIGATIONS.

Owner shall review each Request for Payment and may make such exceptions in accordance with the terms of this Agreement. Not later than forty-five (45) Days after its receipt of a Request for Payment and supporting documentation in the manner, with such detail and at the time herein required, Owner shall make payment to Contractor in the amount required, less (i) any disputed portion of such Request for Payment, (ii) any undisputed amounts payable by Contractor to Owner hereunder from the immediately preceding billing period and (iii) any other Owner withholding rights explicitly set forth herein. Owner shall make payment of the net amount specified in each Request for Payment submitted in accordance with Section 6.3, less (i) any disputed portion of such Request for Payment, (ii) any undisputed amounts payable by Contractor to Owner hereunder from the immediately preceding billing period and (iii) any other Owner withholding rights explicitly set forth herein, not later than the last Business Day of the month immediately following the month in which such Request for Payment was received by Owner; provided, however, that if Contractor submits such Request for Payment to Owner after the 15th day of the relevant month, the time period within which Owner shall be obligated to make payment hereunder shall be extended by such number of days following such 15th day for which such Request for Payment was not submitted. See Exhibit B-4 for an example of such payment procedures.

 

6.7

FINAL PAYMENT.

Within thirty (30) days of the Final Completion Date, Contractor shall submit a final Monthly Progress Report and a final request for payment which shall set forth all amounts due and remaining unpaid to it (the “Final Request for Payment”), and upon approval thereof by Owner, Owner shall pay to Contractor the amount due under such Final Request for Payment. Together with the submission of the Final Request for Payment to Owner, Contractor shall: (a) furnish Owner a Clear Lien and Privilege Certificate pursuant to Section 3.8.58; (b) deliver evidence satisfactory to Owner that Contractor has filed a request for cancellation of the Notice of Contract pursuant to Section 3.8.59 and (c) deliver evidence satisfactory to Owner, including a Payment Status Affidavit from Contractor and all Major Subcontractors in the form of Exhibit F-15 and Exhibit F-16, respectively, and a release and waiver of liens from Contractor and all Major Subcontractors in the form of Exhibit F-3 and Exhibit F-4, respectively, that all claims, liens, security interests or encumbrances in the nature of mechanics’, labor or materialmen’s liens or otherwise, arising out of or in connection with the Facility, Job Site or the performance by Contractor, or any Major Subcontractor, of the Work, have been satisfied or discharged.

 

6.8

OWNER’S RIGHT TO WITHHOLD PAYMENT.

6.8.1 Notwithstanding anything to the contrary contained herein, upon the occurrence and continuance of any of the following events, Owner, upon Notice to Contractor, may withhold or retain such portion (including all) of any payment due to Contractor under this Agreement as reasonably necessary to ensure the performance of the Work or to protect fully Owner’s rights hereunder:

 

48


 

(a) Contractor is in default under Section 31.1 or has otherwise failed to perform any of its material obligations hereunder, but excluding (i) defaults for which the payment of liquidated damages is the sole and exclusive remedy as provided in Article 22, and (ii) costs attributable to any such default that are otherwise Direct Costs as provided in Exhibit B-1;

(b) there exists any outstanding and unpaid payment obligation owing by Contractor;

(c) provided that Contractor is then obligated to indemnify Owner for liens, (i) Contractor is not able to indemnify Owner to Owner’s satisfaction against any such lien that shall be registered against the Job Site, Facility (or any portion thereof), any Materials, any land or improvements pertinent thereto and such lien shall remain undischarged or (ii) Contractor, Owner or the Lenders shall have received any claims for liens arising in connection with this Agreement which have not been withdrawn, all arising as a result of any acts or omission of Contractor or any Subcontractors or Agent For Contractors;

(d) Owner is required in accordance with applicable Laws to withhold Taxes payable by Contractor in respect of the Work;

(e) there is an assessment of any fines or penalties against Owner as a result of Contractor’s failure to comply with applicable Law, Permits or Applicable Codes and Standards;

(f) Contractor has failed to make payments to Subcontractors as required under their respective Subcontracts, excluding the right of Contractor to withhold payments to Subcontractors as provided under the terms of the applicable Subcontract; or

(g) Owner has incurred any other Non-Reimbursable Costs or liabilities for which Contractor is responsible hereunder.

6.8.2 Owner’s right to withhold amounts pursuant to this Section 6.8 shall not be deemed to in any way reduce Owner’s rights to withhold amounts due to Contractor under any other Section hereof. If Owner withholds amounts pursuant to this Section 6.8, Owner shall promptly inform Contractor of the reason therefor and once Contractor has corrected the reasons for the withholding, Owner shall pay the said withheld amount with the next Request for Payment submitted by Contractor. Notwithstanding anything to the contrary contained herein, Contractor shall not have any rights of termination or suspension as a result of Owner’s exercise of its rights under this Section 6.8.

 

49


 

6.9

RELEASE OF LIABILITY.

Acceptance by Contractor of payment pursuant to a Final Request for Payment shall constitute a satisfaction and release by Contractor and each of its Subcontractors in favor of Owner, Owner’s Representative, the Lenders, the Independent Engineer and all Affiliates, officers, directors, employees and agents thereof from all claims and liability hereunder with respect to the Work, or for any act or omission of Owner or of any of the above-listed Persons relating to or affecting this Agreement, except for (a) claims which are the subject of a Dispute filed by either Owner or Contractor prior to the date of such payment pursuant to Article 36, (b) Owner’s indemnity obligations hereunder, (c) any payment that may become due to Contractor under the last sentence of Section 6.7, or (d) any other provision hereof that is expressly intended to survive. Subject to acceptance of the Facility by Owner upon the Facility Substantial Completion Date, no payment shall: (i) be deemed a representation that Owner has inspected the Materials or the Work, (ii) constitute or be deemed an acceptance, in whole or in part, of any portion of the Work or (iii) operate to release Contractor from any obligations or liabilities hereunder.

 

7.

SCHEDULE BONUSES.

 

7.1

INTERIM MILESTONE BONUSES.

7.1.1 In consideration for Contractor’s timely completion of the Work, Owner will, subject to Section 7.4, pay to Contractor, not later than [***] days following the date of achievement, in addition to the amounts payable to Contractor pursuant to Section 6.3, an Interim Milestone Bonus in respect of each corresponding Interim Milestone that Contractor has achieved prior to, on, or within [***] Days following the relevant Completion Date.

7.1.2 If Contractor achieves an Interim Milestone prior to the relevant Completion Date, the amount of the Interim Milestone Bonus payable in respect of such Interim Milestone shall be increased by an amount equal to [***] for each day between the date of such achievement and such Completion Date.

7.1.3 If Contractor achieves an Interim Milestone after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Interim Milestone Bonus payable in respect of such Interim Milestone shall be equal to [***]. If Contractor achieves an Interim Milestone more than [***] Days after the relevant Completion Date but within [***] of the relevant Completion Date, the amount of the Interim Milestone Bonus payable in respect of such Interim Milestone shall be equal to [***]. If Contractor achieves an Interim Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Interim Milestone Bonus payable in respect of such Interim Milestone shall be equal to [***]. For the avoidance of doubt, if Contractor does not achieve an Interim Milestone within [***] Days of the relevant Completion Date, no Interim Milestone Bonus shall be payable in respect of such Interim Milestone.

 

7.2

PRIMARY MILESTONE BONUSES.

7.2.1 In consideration for Contractor’s timely completion of the Work, Owner will, subject to Section 7.4, pay to Contractor, not later than [***] days following the Final Completion Date, in addition to the amounts payable to Contractor pursuant to Section 6.3, a Primary Milestone Bonus in respect of each corresponding Primary Schedule Milestone that Contractor has achieved prior to, on, or within [***] Days following the relevant Completion Date.

 

50


 

7.2.2 If Contractor achieves a Primary Milestone prior to the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be increased by an amount equal to [***] for each day between the date of such achievement and such Completion Date.

7.2.3 If Contractor achieves a Primary Milestone after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. For the avoidance of doubt, if Contractor does not achieve a Primary Milestone within [***] Days of the relevant Completion Date, no Primary Milestone Bonus shall be payable in respect of such Primary Milestone.

 

7.3

SUPER PRIMARY MILESTONE BONUSES.

7.3.1 In consideration for Contractor’s timely completion of the Work, Owner will, subject to Section 7.4, pay to Contractor, not later than [***] days following the Final Completion Date, in addition to the amounts payable to Contractor pursuant to Section 6.3, a Super Primary Milestone Bonus in respect of each corresponding Super Primary Schedule Milestone that Contractor has achieved prior to, on, or within [***] Days following the relevant Completion Date.

7.3.2 If Contractor achieves a Super Primary Milestone prior to the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be increased by an amount equal to [***] for each day between the date of such achievement and such Completion Date.

7.3.3 If Contractor achieves a Super Primary Milestone after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone

 

51


 

shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. For the avoidance of doubt, if Contractor does not achieve a Super Primary Milestone within [***] Days of the relevant Completion Date, no Super Primary Milestone Bonus shall be payable in respect of such Super Primary Milestone.

 

7.4

LIMITATIONS.

7.4.1 Owner’s total liability to Contractor under this Article 7 shall not exceed the Schedule Bonus Cap.

7.4.2 Notwithstanding anything contained herein to the contrary, if at any time Contractor’s Margin is reduced pursuant to Section 8.2 to:

(a) [***], then the aggregate amount of all Schedule Bonuses in respect of which Contractor has been paid or is entitled to be paid shall be reduced by an amount equal to [***] of such aggregate amount;

(b) [***], then the aggregate amount of all Schedule Bonuses in respect of which Contractor has been paid or is entitled to be paid shall be reduced by an amount equal to [***] of such aggregate amount;

(c) [***], then the aggregate amount of all Schedule Bonuses in respect of which Contractor has been paid or is entitled to be paid shall be reduced by an amount equal to [***] of such aggregate amount;

(d) [***], then the aggregate amount of all Schedule Bonuses in respect of which Contractor has been paid or is entitled to be paid shall be reduced by an amount equal to [***] of such aggregate amount;

provided that, for the avoidance of doubt, the reductions described in this Section 7.4.2 shall not be cumulative. If Owner has paid any Schedule Bonus(es) to Contractor prior to such reduction, then Owner may, without prejudice to Section 41.7, deduct from any amounts owed to Contractor hereunder an amount equal to the amount of such reduction.

7.4.3 Notwithstanding anything contained herein to the contrary, if Owner determines that Contractor has not or will not be entitled to payment for any Primary Milestone or Super Primary Milestone pursuant to and in accordance with Section 7.2 and Section 7.3, respectively, Owner shall have no obligation to pay to Contractor any Schedule Bonuses pursuant to this

 

52


 

Agreement. If Owner has paid any Schedule Bonus(es) to Contractor prior to such determination, then Owner may, without prejudice to Section 41.7, deduct from any amounts owed to Contractor hereunder an amount equal to the aggregate amount of all such Schedule Bonuses previously paid.

7.4.4 For the avoidance of doubt, Contractor shall not be entitled to payment in respect of any Schedule Bonus unless and until the achievement of the relevant Schedule Milestone is confirmed by a Certificate of Schedule Milestone Achievement to be provided by Contractor together with the relevant Request for Payment.

 

8.

COST OVERRUN; COST SAVINGS.

 

8.1

TOTAL COSTS.

8.1.1 Contractor acknowledges and understands that Owner has structured its Financing on the basis of the Target Price. Accordingly, Contractor agrees as a consequence that the Contractor’s Margin shall be subject to adjustment under the circumstances described in this Article 8, without impacting Owner’s obligation to reimburse Contractor for Direct Costs incurred by it in accordance with this Agreement.

8.1.2 For the purposes of this Agreement, “Total Costs” means, as of any date, an amount equal to the sum, as calculated by Owner pursuant to Section 8.2.3, of: (a) the Reimbursable Costs, Contractor’s G&A and Contractor’s Margin duly paid to Contractor by Owner pursuant to Section 6.3; (b) the Agent For Contracts Costs; (c) any costs incurred by Owner to perform portions of the Work or any other Contractor obligation that should have been performed by Contractor under this Agreement that are in excess of the amount that Owner would have paid to Contractor to perform such portions of the Work; and (d) any other cost expressed to be included in the calculation of Total Costs hereunder; provided that the Total Costs shall not include the Total Cost Exclusions. For the avoidance of doubt, the calculation of the Total Costs as of the Final Completion Date shall include all such amounts owing, but not yet paid, to Contractor with respect to the Work performed through and including the Final Completion Date, including amounts set forth in the Final Request for Payment.

 

8.2

COST OVERRUN.

8.2.1 In the event that at any time a Cost Overrun exists that is greater than [***], Owner shall be permitted by written notice to Contractor to reduce the Contractor’s Margin for all purposes hereunder as follows:

(a) if the Cost Overrun is greater than [***], but less than or equal to [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***];

(b) if the Cost Overrun is greater than [***] but less than or equal to [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***];

 

53


 

(c) if the Cost Overrun is greater than [***], but less than or equal to [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***]; and

(d) if the Cost Overrun is greater than [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***].

8.2.2 Owner shall be permitted to reduce the Contractor’s Margin pursuant to Section 8.2.1 more than once if following Owner’s first delivery of a notice pursuant to Section 8.2.1 a Cost Overrun increases to exceed the next then applicable threshold set forth therein. Each reduction of Contractor’s Margin effected pursuant to Section 8.2.1 shall be applied both retroactively and prospectively, and all payments by Owner of Contractor’s Margin made prior to such reduction shall be retroactively adjusted to be equal to an amount calculated using the reduced Contractor’s Margin. In such event, without prejudice to Section 41.7, Owner may deduct from any amounts owed to Contractor hereunder an amount equal to the positive difference between the amount of the Contractor’s Margin previously paid to Contractor pursuant to Section 6.3 calculated using the previously applicable Contractor’s Margin and the amount of the Contractor’s Margin previously paid to Contractor as recalculated using the reduced Contractor’s Margin. Each notice delivered by Owner pursuant to Section 8.2.1 shall include Owner’s supporting calculations of the amount of the relevant Cost Overrun and, if applicable, the amount of such positive difference to be deducted from amounts owed to Contractor.

8.2.3 Within thirty (30) days following the Final Completion Date, Owner shall calculate and deliver to Contractor written notice of the amount by which the Total Costs exceed the Target Price, if any, as of the Final Completion Date, such notice to include Owner’s supporting calculations of the amount of such excess.

8.2.4 The Parties acknowledge and agree that (a) the Dollar values in Sections 8.2.1 and 8.2.3 are subject to adjustment pursuant to Section 4.1.4 and (b) the remedies set forth in this Section 8.2 are reasonable and appropriate measures of the damages for the circumstances described herein and do not represent a penalty.

 

8.3

COST SAVINGS.

8.3.1 Within [***] days following the Final Completion Date, Owner shall calculate and deliver to Contractor written notice of the Cost Savings, if any, such notice to include Owner’s supporting calculations of the amount of the Cost Savings. The Cost Savings shall be calculated as of the Final Completion Date. If there is a Cost Savings that is greater than [***], Owner shall make payment of the following amount to Contractor within [***] days of Owner’s delivery of written notice to Contractor:

 

54


 

(a) if the Cost Savings is greater than [***], but less than or equal to [***], an amount equal to [***] of the amount of the Cost Savings;

(b) if the Cost Savings is greater than [***] but less than or equal to [***], an amount equal to [***] of the amount of the Cost Savings;

(c) if the Cost Savings is greater than [***], but less than or equal to [***], an amount equal to [***] of the amount of the Cost Savings; and

(d) if the Cost Savings is greater than [***], an amount equal to [***] of the amount of the Cost Savings.

8.3.2 The Parties acknowledge and agree that the Dollar values in Section 8.3.1 are subject to adjustment pursuant to Section 4.1.4.

 

9.

PERFORMANCE SECURITY.

 

9.1

TYPES OF PERFORMANCE SECURITY.

To secure Contractor’s performance of its obligations hereunder, Contractor acknowledges and agrees that Owner shall have the right to hold (a) the Performance and Payment Bonds and (b) the Contractor Guarantees.

 

9.2

PERFORMANCE AND PAYMENT BONDS.

9.2.1 On or prior to the Notice to Proceed Date or within thirty (30) days after the Effective Date, whichever is later, Contractor shall deliver to Owner a performance bond (in the form of a bank letter of credit that is in form and substance satisfactory to Owner, such form to be included as Exhibit F-9A) and a payment bond (in the form of an insurance surety bond as provided in Exhibit F-9B) issued for the benefit of Owner (the “Performance and Payment Bonds”), in each case issued by a Qualified Surety.

9.2.2 The Performance Bond shall constitute security for all of Contractor’s payment and performance obligations hereunder. The Performance Bond shall have a face amount equal to [***] of the initial Target Price. In the event the Target Price is increased by one or more Change Orders or otherwise in an aggregate amount equal to or greater than [***] in accordance with the terms of this Agreement prior to the Facility Substantial Completion Date, Contractor shall increase the amount of the Performance Bond to reflect the corresponding increase in the Target Price by [***] of such increase, within [***] Days of such increase in the Target Price. Upon Facility Substantial Completion, the face amount of the Performance Bond shall be reduced to an amount equal to [***] of the then current Target Price. The Performance Bond will be held by Owner until the expiration of the Warranty Period.

 

55


 

9.2.3 The Payment Bond shall constitute security for the payments made by Owner to Contractor on or after the Notice to Proceed Date. The Payment Bond shall have a face amount equal to a variable percentage of the initial Target Price, as follows: (i) as of the Notice to Proceed Date, the face amount of the Payment Bond shall be equal to [***] of the initial Target Price; (ii) on the date that is [***] days following the Notice to Proceed Date, the face amount of the Payment Bond shall be increased to be equal to [***] of the initial Target Price; (iii) on the LPS5 Substantial Completion Date, the face amount of the Payment Bond shall be decreased to be equal to [***] of the initial Target Price; and (iv) on the LPS6 Substantial Completion Date, the face amount of the Payment Bond shall be decreased to be equal to [***] of the initial Target Price. The Payment Bond will be held by Owner until the Facility Substantial Completion Date.

9.2.4 In the event amounts are due under this Agreement from Contractor to Owner (including Schedule Delay Liquidated Damages), and such amounts are not paid by Contractor when due, Owner shall have the right, commencing [***] Business Days following Owner’s delivery of written notice thereof to Contractor, to draw amounts under the Performance Security equal to the amount owing by Contractor.

9.2.5 If at any time the surety that has issued the Performance and Payment Bonds is no longer a Qualified Surety, then Contractor shall replace such Performance and Payment Bonds with a replacement instrument complying with the terms hereof from a Qualified Surety within [***] Business Days from receiving notice from Owner.

 

9.3

CONTRACTOR GUARANTEES.

9.3.1 On the Effective Date, Contractor shall deliver an executed Contractor Guarantee from each Contractor Guarantor. Contractor shall cause each of the Contractor Guarantees to remain in full force and effect until the expiration of the Warranty Period. Contractor acknowledges that Owner shall have the right, in its sole discretion, to issue demands for payment under either or both of the Contractor Guarantees.

9.3.2 As soon as available, but in any event within [***] Days after the end of the first three fiscal quarters of each Contractor Guarantor, Contractor shall deliver to Owner the unaudited and consolidated balance sheet of such Contractor Guarantor, as of the end of such quarter, the related consolidated statements of income, cash flows, and retained earnings and stockholders’ equity for such quarter, all of which shall be certified by the chief financial officer or equivalent officer of such Contractor Guarantor subject to normal year-end audit adjustments. As soon as available, but in any event no later than [***] Days after the end of each fiscal year of each Contractor Guarantor, Contractor or such Contractor Guarantor shall deliver to Owner a copy of the audited consolidated balance sheets at the end of each such year as well as the related consolidated statements of income, retained earnings, and cash flows for such year. All financial statements delivered pursuant to this Section 9.3 shall be complete and correct in all material respects and shall be prepared in accordance with generally accepted accounting principles applied consistently throughout the periods reflected therein. If a Contractor Guarantor makes the foregoing financial statements publicly available on its website or through filings pursuant to applicable securities laws, then the requirements of this Section 9.3 shall be deemed met by such Contractor Guarantor making such financial statements publicly available in accordance with the requirements of applicable securities laws or, otherwise, in accordance with its customary practice.

 

56


 

10.

QUALITY CONTROL AND INSPECTION.

 

10.1

QUALITY MANAGEMENT PLAN.

Within thirty (30) Days after the earlier of the Limited Notice to Proceed or Notice to Proceed, and prior to commencing any aspect of the Work, Contractor shall have submitted for Owner’s review and approval, and Owner shall have approved, as being in accordance with Owner Standards, a formal program for inspecting and testing all aspects of the Work (the “Quality Management Plan”). Owner shall have a period of thirty (30) Days following submittal to it of the Quality Management Plan to approve or comment upon the Quality Management Plan. If Owner approves the Quality Management Plan, or Owner does not approve or provide comments on the Quality Management Plan within such thirty (30) Day period, then Contractor may proceed to implement such Quality Management Plan; provided, however, that Owner may at any time require Contractor to amend the Quality Management Plan if it is not in accordance with the requirements of this Agreement. The individual(s) responsible for implementing the Quality Management Plan shall be identified by Contractor to Owner.

 

10.2

DEFECTS AND DEFICIENCIES.

10.2.1 Contractor shall perform, or cause to be performed, quality control and inspection activities related to the Work as required by the Contractor’s Quality Management Plan, this Agreement and Owner Standards. Prior to entering any purchase orders for Materials or any Subcontracts, Contractor shall provide Owner the quality control and inspection program for such Subcontractor, and Contractor shall (i) ensure that each such program is substantially the same as the approved Quality Management Plan, and (ii) require each such Subcontractor to provide periodic reports and maintain accurate and ongoing records showing compliance with each such quality control and inspection program. The Quality Management Plan must be adequate to meet the quality control and inspection needs of the Work, and Contractor may not rely upon Owner or any other Person or Government Authority to provide such services. Contractor shall inspect and test the Work, including all design, engineering, installation, Materials, tools and supplies performed or provided. All Defects or Deficiencies identified by such inspection or testing shall be included in the Monthly Progress Report submitted to Owner with the Contractor’s Request for Payment. The Monthly Progress Report shall describe in detail (a) all such Defects or Deficiencies identified, including a failure analysis of the problem, (b) a description of the solutions identified for each such Defect and Deficiency, (c) all Work that was re-performed or corrected and any related services rendered during the immediately preceding month and (d) all such Defects or Deficiencies not then corrected or re-performed. Contractor shall identify a solution for each such Defect and Deficiency as soon as possible, but in any event not later than seven (7) days after the date that such Defect and Deficiency is identified, and, in the case of known defects or deficiencies in Owner Furnished Equipment and Materials, notify and request a solution from Owner or Owner Contractors.

 

57


 

10.2.2 Contractor shall correct, or cause to be corrected, all Defects and Deficiencies as soon as practicable under the circumstances, and shall correct, or cause to be corrected, (a) any Defects or Deficiencies identified during the design process prior to the date that the procurement process begins, (b) any Defects or Deficiencies identified during the procurement process prior to the date that the shipping of Materials and equipment begins, (c) any Defects or Deficiencies identified during the performance of the Work prior to the start of the Demonstration Tests, (d) any Defects identified during the Demonstration Tests prior to the start of the Performance Tests (excluding Punch List Items) and (e) any Defects or Deficiencies identified during the Performance Tests prior to re-running the Performance Tests (excluding Punch List Items); provided that with respect to clauses (a) through (e) above, Contractor shall have the right, upon prior written notice to Owner, to re-sequence the Work (including not correcting the Defects in the order required by this Section 10.2.2) as necessary to correct such Defects or Deficiencies as efficiently and expeditiously as possible.

 

10.3

INSPECTION RIGHTS.

Owner and the Owner Designees shall have the right to inspect in accordance with Owner Standards all Work performed in accordance with this Agreement and any item of Materials, service or workmanship to be provided in accordance with this Agreement as and to the extent described in Exhibit A or referred to elsewhere herein, and Contractor shall arrange such inspection, at the request of Owner, at any location that Work is performed or where Materials are fabricated or stored. With respect to tests which Contractor is required to perform hereunder pursuant to Exhibit A or Exhibit R, whether the tests take place at Contractor’s factory, or at the factory of a Subcontractor or Agent For Contractor, or the Job Site, Contractor shall supply all necessary labor, materials, equipment, apparatuses, instruments and competent test personnel who shall be able to take complete charge of the tests, and shall be authorized to represent and make decisions for the proper carrying out of the tests; provided, however, that with respect to any test set forth in Exhibit A or Exhibit R which Owner or the Owner Designees are entitled to witness, Contractor shall not be required to re-perform such test by virtue of Owner’s or the Owner Designees’ failure to observe same if Owner shall have been given at least fifteen (15) Days’ notice thereof (except for routine in process inspections). Owner shall at any time have the right to reject, or to direct Contractor to reject, any such portion of the Work, including any design, engineering, Materials, installation, tools or supplies, which in Owner’s reasonable judgment do not conform to the provisions hereof, including the requirements set forth in Exhibit A and the Drawings and Specifications, or which contain Defects or Deficiencies. Upon such rejection, Contractor shall as soon as practicable under the circumstances, but in no case later than the commencement of the Performance Tests, remedy any such condition identified by Owner as giving rise to such rejection. In the case of discovered defects or deficiencies in Owner Furnished Equipment or Material, Contractor shall promptly notify Owner. Copies of all test certificates, performance curves and data sheets required by Owner shall be supplied by Contractor to Owner’s Representative in reproducible form. Sufficient information is to be given on all test certificates, performance curves and data sheets to enable the Materials to which they refer to be identified.

 

10.4

THIRD PARTY INSPECTION.

Contractor understands that the Owner Designees or the Lenders, and certain Government Authorities have or shall have the right, from time to time, to observe and inspect the Work and the Facility and to observe all tests of the Work and the Facility. Contractor shall allow such third-party inspectors access to the Work and the Facility and to the Contractor’s technical and design

 

58


 

records pertaining thereto, so long as either Owner’s Representative is present or Contractor has obtained the prior written approval of Owner. Owner agrees to protect as confidential anything designated by Contractor as such, whether by notation thereon or separate Notice; provided that in no event shall Owner be liable to Contractor for the failure of any party (other than Owner) to comply with the confidentiality requirements of Contractor.

 

10.5

EFFECT OF WAIVER OF INSPECTION RIGHTS.

In the event that Owner or the Owner Designees shall waive or fail to exercise their right to test and inspect as herein provided, such waiver or failure shall in no way relieve Contractor of its obligations to perform the Work, or any part of it, in accordance with this Agreement, nor shall such waiver or failure prejudice or affect the rights of Owner or the Owner Designees set forth herein; nor shall any test or inspection by Owner, any Lenders or the Owner Designees or any failure to test or inspect be construed as an approval or acceptance of the Work or any part thereof. However, if any test or inspection is otherwise successful, the failure of any or all of Owner or the Owner Designees to attend such test or inspection shall not alter the successful nature of the test or inspection; provided, however, that Contractor shall promptly provide to Owner detailed information of the test or inspection, including the information specified in Section 10.3.

 

11.

HEALTH, SAFETY, SECURITY AND ENVIRONMENT

 

11.1

COMPLIANCE.

Contractor shall be a “prime contractor” for all purposes under the Occupational Safety and Health Act of 1970 and shall take all actions necessary or advisable to ensure compliance with OSHA regulations and the health and safety of all persons at the Job Site, or portion thereof, until the earlier of (a) Owner’s issuance of written notice that Owner will assume the role of prime contractor for the Job Site, or such area or areas within the Job Site as specified in such notice, and (b) the termination of this Agreement.

 

11.2

HSSE PROGRAM.

11.2.1 Within sixty (60) Days after the Effective Date, and prior to commencing any aspect of the Work, Contractor shall have submitted for Owner’s review and approval, and Owner shall have approved, as being in accordance with Owner Standards and Exhibit U, a formal health, safety, security and environment program (the “HSSE Program”). Owner shall have a period of thirty (30) Days following submittal to it of the HSSE Program to approve or comment upon the HSSE Program. If Owner approves the HSSE Program, or Owner does not approve or provide comments on the HSSE Program within such thirty (30) Day period, then Contractor may proceed to implement such HSSE Program; provided, however, that Owner may at any time require Contractor to amend the HSSE Program if it is not in accordance with the requirements of this Agreement, including those set forth in Exhibit U. The individual(s) responsible for implementing the HSSE Program shall be identified by Contractor to Owner. Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work in accordance with applicable Law, the Contractor’s safety procedures and Owner Standards.

 

59


 

11.2.2 Contractor shall provide sufficient supervision for health, safety, security and environmental protection (“HSSE”) and take all precautions necessary to provide all protection to prevent damage, injury or loss to (a) all employees engaged in connection with the Work and all other Persons who may be affected thereby, (b) all the Work and all Materials to be incorporated therein, whether in storage on or off the Job Site, under the care, custody or control of Contractor or any Subcontractors or Agent For Contractors, (c) other property at the Job Site or adjacent thereto or the access route to the Job Site, including trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction or (d) the environment (except as otherwise permitted under any Permit); provided that Contractor’s obligations in regard to (b), (c) and (d) shall be to comply with applicable Law, Permits, Owner Standards and the HSSE Program.

 

11.3

SAFEGUARDS.

Contractor shall erect and maintain, as required by existing conditions and progress of the Work, all HSSE-related safeguards, including physical barriers, fences and railings. Contractor shall post danger signs and other warnings against hazards, promulgate safety regulations and notify owners and users of adjacent utilities of any dangerous or hazardous conditions. In accordance with Laws, Permits, Applicable Codes and Standards, and Owner Standards, Contractor shall exercise the utmost care in the use and handling of explosives or other Hazardous Substances or equipment and only competent, trained and experienced employees of Contractor or of any Subcontractor or Agent For Contractor shall be permitted to handle such explosives or other Hazardous Substances or equipment. All warning signs and notices shall be in English, Spanish and such other language as appropriate so that the safety communications will be understood by all personnel.

 

11.4

HSSE INCIDENTS.

Contractor shall have the following HSSE incident and near miss reporting obligations:

11.4.1 Contractor shall report in writing to Owner (and, to the extent required by any applicable Law, Applicable Codes and Standards or applicable Permit, the appropriate Government Authority) details of any HSSE-related incident that occurs on or in the vicinity of the Job Site as soon as possible after its occurrence, but in any event no later than twenty-four (24) hours after such HSSE-related incident occurs. In the case of any fatality or Severe Injury, Contractor shall immediately (a) notify Owner (and, to the extent required by any applicable Law, Applicable Codes and Standards or Permits, the appropriate Government Authority), (b) stop all Work on or in the vicinity of the Job Site, (c) and schedule a meeting as soon as practical (but no later than twenty-four (24) hours after the occurrence of such fatality or Severe Injury) with Owner to review the incident and, if necessary and/or required by Owner, revise the Contractor’s HSSE precautions and programs. Following any meetings with Owner pursuant to this Section 11.4.1, Contractor shall implement all reasonable revisions to the Contractor’s safety precautions and programs as required by Owner, and upon Notice from Owner, Contractor shall recommence the performance of the Work. Contractor shall initiate incident investigations as soon as practical (but no later than forty-eight (48) hours after the occurrence of such HSSE-related incident). Owner shall be invited to participate in all investigations, and may elect to be an active participant in any investigation and reserves the right to perform a parallel investigation. Contractor shall promptly

 

60


 

send Owner copies of all citations issued by a Government Authority against Contractor resulting from or relating to an incident while performing the Work. Contractor shall report any HSSE-related incident and near misses at weekly HSSE meetings for review and discussion. Any delays in, or additional costs incurred in connection with, the Work resulting from the Contractor’s compliance with this Section 11.4.1 shall not form the basis for a Change Order.

11.4.2 In the event of any emergency situation that endangers or could endanger life, property or the environment, Contractor shall take such action as may be reasonable and necessary to prevent, avoid or mitigate injury, damage or loss and shall, as soon as possible, report any such incidents, including the Contractor’s response and actions with respect thereto, to Owner.

11.4.3 Whenever Owner shall, in its sole discretion, determine that such an emergency situation exists, or is imminent, with respect to any part or all of the Work or other activities on the Job Site, Owner shall have the right to occupy and control the Job Site and, should Owner deem it necessary, to modify any aspect of the Work related to such emergency situation including stopping or altering the Work.

 

12.

CHANGES IN THE WORK.

 

12.1

GENERAL.

12.1.1 Owner may at any time order changes to the Work. Contractor may propose changes to the Work for Owner’s consideration; provided that Owner shall not be obligated to approve any such change. Contractor shall be entitled to receive a Change Order in accordance with the provisions of Section 12.1.2 with respect to: (a) Force Majeure Events; (b) Owner Caused Delays; (c) Owner-directed or approved changes; (d) an act, omission or failure by Owner (in its capacity as owner under the Phase 1 Agreement) under the Phase 1 Agreement or an act, omission or failure by any party for which Owner (in such capacity) is responsible with respect to the Phase 1 Facility that demonstrably and adversely affects Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule under this Agreement (except in each case to the extent such affects on Contractor’s costs and/or ability to perform has already been addressed through an executed change order under the Phase 1 Agreement); (e) any failure by an Owner Contractor to perform its material obligations under the relevant Owner Contract that demonstrably and adversely affects Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule; (f) any error, inaccuracy or omission in or change by Owner to the Relied Upon Information that demonstrably and adversely affects Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule; (g) as provided elsewhere in this Agreement including in Sections 4.1.4, 12.4 and 16.3.2; (h) Pre-Existing Hazardous Substances which demonstrably and adversely impact Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule (except to the extent any additional costs or delay is the result of Contractor’s, its Subcontractors’ or Agent For Contractor’s Grossly Negligent act or omission or Willful Misconduct in the handling, storage or transportation of any Pre-Existing Hazardous Substance after discovery by Contractor, a Subcontractor or Agent For Contractor); (i) suspensions in the Work in accordance with Section 17.1.1 or Section 17.1.3, (j) a Carrollton Gage Delay; (k) any soils improvement cement reagent adjustment; and (l) any impact described in clauses (c), (f), (h) or (k) that arises under or relates to “Work” (as that term is defined under the Phase 1 Agreement) under the Phase 1 Agreement (except in each case to the extent such impact

 

61


 

has already been addressed through an executed change order under the Phase 1 Agreement); provided that, with respect BH Testing Delay, the Change Order which shall be limited to a day-for-day extension of the applicable LNG Production System Substantial Completion Date or the Facility Substantial Completion Date, as the case may be, equal to the number of days of such BH Testing Delay.

12.1.2 Contractor shall be entitled to receive only one Change Order with respect to the same act or event and shall not be entitled to aggregate the cumulative impact of such act or event or two or more acts or events. Unless a particular activity is demonstrated to adversely impact an LNG Production System Substantial Completion Deadline or the Facility Substantial Completion Deadline, no adjustment to such LNG Production System Substantial Completion Deadline or Facility Substantial Completion Deadline, as applicable, shall be made, and any adjustments to the Project Schedule made in connection with a Change Order shall take into account any available float for such activity that is affected by a Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable.

12.1.3 Except for Owner-directed changes under Section 12.3, all changes in the Work shall be authorized by a written Change Order executed by Owner and Contractor. Any such Change Order shall be accompanied by additional and/or revised Drawings and Specifications, as reasonably necessary, and shall be priced as provided in Section 12.2. All such changes shall be performed under and governed by the provisions hereof and the relevant Change Order. Contractor acknowledges and agrees that the Independent Engineer is not an agent of Owner and is not authorized to execute Change Orders on behalf of Owner.

12.1.4 Contractor agrees that any Change Order shall constitute the final and complete compensation and satisfaction for all costs and schedule effects related to (a) the implementation of the stated changes, (b) the cumulative impact of effects resulting from the stated changes on all prior Work and changes in the Work to be performed as scheduled and (c) any costs associated with expediting the Work to mitigate the effect of any change or delay which costs shall be included in the Change Order. Contractor expressly waives any claims for additional compensation, damages or time extension in connection with the stated changes; provided, however, that if a Dispute exists with respect to any Change Order (whether proposed by Contractor or Owner), such Dispute shall be resolved pursuant to the dispute resolution provisions set forth in Article 36.

12.1.5 No Change Order shall be issued in connection with any Defects or Deficiencies on the part of Contractor or any Subcontractor or Agent For Contractor in the performance of the Work hereunder. No Change Order shall be issued in connection with the performance or completion of the Pre-Approved Site Work.

12.1.6 No Change Order request by Contractor shall be permitted after the Final Request for Payment is submitted. The Parties shall not be bound to any changes to the Work or this Agreement unless expressly set forth in a Change Order that has been signed by both Parties (or solely by Owner under Section 12.3.1) or determined in accordance with the dispute resolution procedures set forth in Article 36.

 

62


 

12.1.7 Contractor shall not comply with any oral changes in the Work received from or on behalf of Owner.

12.1.8 Except as specifically set forth in a Change Order, no Change Order shall modify or affect: (a) the Work or the requirements set forth herein; (b) the Target Price; (c) the Project Schedule; (d) the Critical Path; (e) any Applicable Deadline, (f) the Demonstration Tests or the Performance Tests; or (g) any other right, liability or obligation of Contractor hereunder.

 

12.2

CHANGE ORDER PROCESS.

12.2.1 Contractor shall provide Notice to Owner as soon as practicable, but no later than five (5) Business Days, after the time when Contractor knows of the impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that will impact the Work. Failure to provide such Notice within ten (10) Business Days after the time when Contractor knows of the impact of any Force Majeure Event shall be deemed to be a waiver of the Contractor’s right to receive a Change Order with respect thereto. Such Notice shall, to the extent practicable, specify the estimated impact on the Target Price and/or the Project Schedule, as applicable, the impact upon the various portions of the Work occasioned by reason of such Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, and shall substantiate the foregoing to the satisfaction of Owner. In the event that Contractor does not know or is unable to specify with reasonable certainty the impact upon the Work at the time such Notice is to be delivered, Contractor shall instead provide Owner with a notice of a potential or anticipated impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that could impact the Work, and shall thereafter provide Owner (and, if requested by Owner, the Independent Engineer) with periodic supplemental Notices during the period that the Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable, continues, detailing any developments, progress or other relevant information of which Contractor is aware. To the extent Owner (in consultation with the Independent Engineer with respect to a Material Change) agrees with the Contractor’s determination of a Force Majeure Event or Owner Caused Delay or any other basis for a Change Order, as applicable, and the effects thereof, Owner shall notify Contractor of Owner’s acceptance. In the event Owner (in consultation with the Independent Engineer with respect to a Material Change) does not accept the Contractor’s findings, Owner or Contractor shall be permitted to dispute such Change Order in accordance with Article 36, and Contractor shall be paid for any Work performed in respect of such disputed Change Order as provided in Section 12.2.5.

12.2.2 As soon as practicable, and in any event within fifteen (15) Days (or such other period as is mutually agreed by Owner and Contractor) after receipt from Owner of a request for a change or Notice of Owner’s acceptance under Section 12.2.1, Contractor shall submit to Owner a proposal for implementing the change indicating the estimated change to the Target Price and/or the Project Schedule, as applicable. If Owner (having consulted with the Independent Engineer in the case of a Material Change) agrees that the Contractor’s proposal should be implemented, Owner (having consulted with the Independent Engineer in the case of a Material Change) shall issue a Change Order incorporating such proposal. Upon receiving such Change Order, Contractor shall diligently perform the change in accordance with the terms thereof.

 

63


 

12.2.3 Contractor’s proposal required pursuant to Section 12.2.2 shall consist of: (a) a detailed material take-off with supporting calculations in accordance with the pricing structure herein, for pricing the change, (b) revisions, if any, to the Drawings and Specifications, (c) a schedule for the work associated with the proposed change, (d) the effect, if any, to the Target Price and/or the Project Schedule, as applicable, (e) the effect, if any, of the change on the Work, including the Performance Tests and/or Demonstration Tests (or protocol therefor), (f) changes, if any, to any right, liability or obligation of a Party or any other provision hereof and (g) changes, if applicable, to any Applicable Deadline.

12.2.4 Contractor’s supporting calculations shall show: (a) the estimated unit quantities, home office and Job Site manpower, Material usage and services to be added and/or deducted by size, type and/or amount provided; (b) the industry estimating reference or other basis used to determine prices, man-hours per unit of installed Materials, rental rates and other similar cost standards; (c) detailed cost breakdown for manpower, engineering and Materials; (d) the Contractor’s Margin; and (e) impacts, if any, to the Critical Path.

12.2.5 Contractor shall not suspend performance of this Agreement during the review and negotiation of any change (regardless of whether such change is proposed by Contractor or Owner), except as may be directed by Owner. Contractor shall commence and perform the changed Work specified in the Change Order issued by Owner under Sections 12.2.2 or 12.3.1, on a cost-reimbursable basis, using Exhibit B-1 and Exhibit C as the basis for such compensation. In the event Owner and Contractor are unable to reach agreement for pricing of a change, or time for performance of changed Work, disagreements regarding such Change Order shall be subject to the dispute resolution procedures set forth in Article 36. Pending resolution of the Dispute, Contractor shall perform the Work as specified in such Change Order and Owner shall continue to pay Contractor all Direct Costs and Contractor’s G&A and Contractor’s Margin applicable thereto associated with such Change Order.

 

12.3

DISPUTED CHANGES.

12.3.1 If Owner (having consulted with the Independent Engineer in the case of a Material Change) disagrees in any way with any proposal of Contractor under Section 12.2, Owner may issue a Change Order to Contractor changing the Work and/or Project Schedule, which Change Order is executed solely by Owner, and Contractor shall be entitled to payment as set forth in Section 12.2.5 and the impact to the Target Price and/or the Project Schedule, as applicable, shall be resolved pursuant to the dispute resolution procedures set forth in Article 36.

12.3.2 Any Change Order executed solely by Owner shall be accompanied by the Contractor’s proposal marked to show Owner’s modifications thereto and shall order Contractor to implement the change in accordance with the proposal as modified by Owner.

 

12.4

CHANGES DUE TO UNKNOWN SUBSURFACE CONDITIONS.

12.4.1 Contractor shall be entitled to receive a Change Order to the extent that it encounters subsurface conditions including geotechnical conditions, archaeological artifacts, fossils, underground utilities or manmade structures which materially differ from, or were not disclosed or provided to Contractor by Owner in Exhibit M or the Geotechnical Reports or which

 

64


 

were not identified by Contractor (or were not reasonably inferable or foreseeable) on the basis thereof, that (a) cannot be safely removed by heavy equipment present at the Job Site at no additional cost and without delay to Contractor, (b) are not Job Site Conditions and (c) cause an increase in the cost to complete the Work or cause a delay in Contractor’s performance of any Critical Path activities, to the extent actually and demonstrably caused by the existence of such geotechnical conditions, archaeological artifacts, fossils, underground utilities or manmade structures.

12.4.2 In the event Contractor encounters any conditions listed in Section 12.4.1 at the Job Site, Contractor shall leave such sites untouched and protected by fencing and shall immediately stop any Work affecting the area. Contractor shall notify Owner of any such discovery as soon as practicable, and Contractor shall carry out Owner’s instructions for dealing with the same. Contractor shall prevent its personnel, its Subcontractors’ personnel, the Agent For Contractors’ personnel and any other Persons from removing or damaging any such article or thing.

 

12.5

INFORMATION REQUESTS.

Owner may request that Contractor provide written information (prior to the issuance of a request for change) regarding the effect of a contemplated change on (a) the Work or the requirements set forth in Exhibit A, (b) the Target Price, (c) the Project Schedule, (d) the Critical Path, (e) any Applicable Deadline, (f) the Demonstration Tests or Performance Tests or (g) any right, liability or obligation of Contractor hereunder. The purpose of such a request will be to determine whether or not a change will be requested. Contractor shall provide the requested information within fourteen (14) Days after the receipt of said request. Such an information request by Owner is not a Change Order and shall not be construed to authorize Contractor to commence performance of the contemplated change in the Work.

 

13.

PROJECT SCHEDULE AND MONTHLY PROGRESS REPORTS.

 

13.1

GENERAL.

Contractor shall prosecute the Work in accordance with or in advance of the Project Schedule; provided, however, that any failure of Contractor to adhere to the Project Schedule, for reasons which are not otherwise excused hereunder, shall not limit or otherwise reduce its obligations or liabilities hereunder.

 

13.2

PROJECT SCHEDULE.

13.2.1 Contractor shall develop, deliver and maintain the Project Schedule in accordance with Exhibit E. The Project Schedule shall be the reference schedule for the duration of the Work, and shall be in the form of Exhibit D.

13.2.2 Except as provided in Article 12 or otherwise expressly in accordance with Exhibits D and E, Contractor shall not make any alterations to the Project Schedule. During the performance of the Work, Contractor and Owner (including Owner’s Representative or his designee, and any other Persons designated by Owner, and the Contractor’s Key Personnel) shall, at a minimum, conduct meetings as provided in Exhibit E for the purpose of reviewing the progress of the Work, the latest Monthly Progress Report, the Quality Management Plan, the HSSE

 

65


 

Program, the Contractor’s, Subcontractors’ and Agent For Contractors’ adherence to the requirements set forth in Exhibit A, the Critical Path and the Project Schedule as well as the status of any claims on the Facility, the Job Site or the Work and claims submitted pursuant to the terms of this Agreement.

 

13.3

MONTHLY PROGRESS REPORTS.

Contractor shall prepare and submit a monthly report meeting the requirements of Exhibit I (each, a “Monthly Progress Report”) to Owner, Owner’s Representative and the Independent Engineer with each Request for Payment but in no event later than the tenth (10th) day of each month. Submission of Monthly Progress Reports shall continue until Contractor has completed all Work that is known to be outstanding at the time of Final Completion. Monthly Progress Reports shall include information relating to the performance of the Owner Contractors and the other information set forth in Exhibit I. The Parties agree that slippages in the Critical Path caused by Contractor, its Subcontractors or Agent For Contractors may be remedied by recovery plans and acceleration plans in accordance with Section 16.3, consisting of critical services, expediting of critical Material and equipment, the addition of productive construction equipment, additional competent supervision and other similar beneficial resources. It is further agreed that slippages in the Project Schedule known to Contractor will not be concealed from Owner, the Independent Engineer or the Lenders in the monthly reports.

 

14.

TRAINING.

Contractor shall be responsible for training Owner’s and/or its Affiliate’s regular operating personnel listed in Exhibit Q in accordance with Exhibit G. Training aids shall be provided by Contractor as required to adequately present the subject material. The general topics of the training will encompass reasonable information necessary for efficient and proper operation of each LNG Production System and the Facility, including operation, maintenance and repair. Training will consist of classroom, on-the job operational training and training using simulation software as necessary to comply with the requirements of this Article 14 and the requirements set forth in Exhibit A. Contractor shall design and submit an outline of a training program to Owner within one hundred eighty (180) Days after the Notice to Proceed Date and a detailed training program one hundred eighty (180) Days prior to commencement of training. Owner shall have a period of thirty (30) Days following submittal to it of the training program outline or detailed program to approve or comment upon each submittal. Contractor shall effect changes in response to Owner’s comments and resubmit the training procedures for Owner’s review and approval within fifteen (15) Days of receipt of such comments from Owner, and Owner shall have a further period of fifteen (15) Days following such resubmittal to approve. Contractor shall conduct at least one (1) full course of training prior to the start of any Pre-Commissioning activities. The training documentation and instruction shall be in the English language. All of the Contractor’s training personnel will speak fluent English as reasonably determined by Owner. All training provided by Contractor shall stress strict compliance with the operation and maintenance manuals, operating instructions, system checklists and/or procedures. If any of the Contractor’s training personnel repeatedly allow, encourage or demonstrate any attitudes or work practices that are not in strict compliance with the operation and maintenance manuals, operating instructions, system checklists and/or procedures, such training personnel shall be replaced by Contractor.

 

66


 

15.

TESTING.

 

15.1

FACTORY TESTS.

Contractor shall perform all customary or required factory tests of all of the Materials in accordance with the requirements set forth in Exhibit A or Exhibit R or by Owner Standards. Contractor shall issue a test memorandum to Owner no later than thirty (30) Days prior to the commencement of each factory test, which memorandum shall describe the factory test to be performed, the applicable item of Material being tested, the standards and method of testing, and the testing facility’s capabilities and shall state a proposed test date. Owner’s Representative and the representative of the Independent Engineer shall be permitted to attend and participate in all such factory tests. Contractor shall provide the results of such required factory tests to Owner within ten (10) Days of the completion of each such factory test. Successful completion of such factory test shall be a precondition to shipment of the tested item of Material.

 

15.2

DEMONSTRATION TESTING.

15.2.1 Contractor shall submit Demonstration Test procedures and a level 3 Demonstration Test schedule at least sixty (60) Days before commencement of the Demonstration Tests in accordance with (and as defined in) Exhibit R. Prior to commencing any Demonstration Tests, Contractor shall submit to Owner a certification that the Facility is free of known Defects and Deficiencies and ready for performance of the Demonstration Tests in accordance with Exhibit R. Owner shall be given at least ten (10) Business Days’ prior Notice by Contractor of the commencement of any Demonstration Tests so that Owner can schedule its and/or its Affiliate’s personnel to witness such Demonstration Tests.

 

15.3

PERFORMANCE TESTING.

15.3.1 Unless Owner otherwise consents in writing (which consent may be withheld in Owner’s sole discretion and for any reason), Contractor must complete all Demonstration Tests, as applicable, and remedy all Defects or Deficiencies, which have been identified by such Demonstration Tests, prior to the start of any Performance Tests.

15.3.2 Owner or its Affiliate will cause qualified and experienced personnel to be available to Contractor for use in executing the Performance Tests and any rerun thereof in compliance with this Agreement and Exhibit R. Contractor shall direct and remain responsible for the actions or omissions of the operation and maintenance personnel (including the personnel of Owner or its Affiliate) during the Performance Tests. In addition, Contractor shall provide the services necessary at the Job Site for the installation, start-up and performance of the Commissioning of each LNG Production System and the Facility and the running or rerunning of the Performance Tests in accordance with the requirements of the Performance Tests and the provisions hereof. The Contractor’s Representative shall have full authority to represent Contractor and to acknowledge Defects or Deficiencies in the Facility, direct the proper conduct of remedial actions relating to the performance of the Facility and the execution of the Performance Tests.

15.3.3 Contractor shall provide preliminary Notice to Owner and the Independent Engineer not less than ninety (90) Days prior to the date that Contractor expects the relevant Work and/or Owner Furnished Equipment and Materials to be ready for the Performance Tests.

 

67


 

Contractor shall provide an additional Notice to Owner and the Independent Engineer not less than five (5) Business Days prior to the date that Contractor will perform the Performance Tests. The Performance Tests for an LNG Production System or the Facility, as applicable, shall be executed as soon as practicable after LNG Production System Mechanical Completion of such LNG Production System or Facility Mechanical Completion, as applicable, and completion of the Demonstration Tests, as applicable, for such LNG Production System or the Facility; provided that, at Owner’s direction, Contractor shall take into account the interim operations of the Facility by Owner and Owner’s contractual commitments to purchasers of LNG to be produced and loaded at the Facility in scheduling Performance Tests. For the avoidance of doubt, the Parties agree that LNG Production System Mechanical Completion of an LNG Production System or Facility Mechanical Completion, as applicable, will precede the start of the performance of the Demonstration Tests, as applicable, for such LNG Production System or the Facility and that the Demonstration Tests, as applicable, for an LNG Production System or the Facility will precede the start of the Performance Tests for such LNG Production System or the Facility. It is further agreed that Defects or Deficiencies affecting the safe, proper or reliable operation of an LNG Production System which are discovered prior to achieving LNG Production System Mechanical Completion of an LNG Production System or Facility Mechanical Completion, as applicable, will be remedied before starting the Demonstration Tests, as applicable, for such LNG Production System or the Facility and any such Defects discovered during the performance of the Demonstration Tests, as applicable, for such LNG Production System or the Facility will be remedied prior to the performance of the Performance Tests for such LNG Production System or the Facility. Defects or Deficiencies discovered during any Performance Tests may, in the sole, reasonable judgment of Owner, require remedy and a subsequent Performance Test; provided, that, if the immediately prior Performance Test was successfully passed, then any subsequent Performance Test shall not prevent Contractor’s achievement of LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable. Notices by Contractor certifying that each of the aforementioned stages have been completed in full compliance with this Agreement must be accepted by Owner in writing.

15.3.4 Contractor shall be responsible to perform all Work necessary, including to correct any Defects and Deficiencies, for (i) “LPS4” (as such term is defined in the Phase 1 Agreement) as described in Exhibit R and (ii) the Facility to successfully pass the Performance Tests described in Exhibit R (including the 72-hour Facility System Reliability Test) (the “Facility Performance Tests”). If: (a) Contractor performs the Facility Performance Tests in accordance with this Agreement and the Facility fails to successfully pass all of the Facility Performance Tests [***] times, or (b) Contractor performs the Facility Performance Tests in accordance with this Agreement and the Facility fails to successfully pass all of the Facility Performance Tests within [***] days after the LPS6 Substantial Completion Date (the earlier to occur of such events, the “Make Good Commencement Date”), then from and after the Make Good Commencement Date Contractor shall be obligated hereunder to perform all Work necessary to successfully pass all of the Facility Performance Tests as soon as reasonably practicable following the Make Good Commencement Date, subject to any Owner Caused Delay impacting its performance after the Make Good Commencement Date, at its sole cost and expense. Notwithstanding anything contained herein to the contrary, Owner shall have no obligation to pay any Direct Costs, Contractor’s G&A or Contractor’s Margin incurred by Contractor after the Make Good Commencement Date in connection with such Work (excluding, for the avoidance of doubt, any Work that is necessary solely to facilitate the performance by an Owner Contractor of its

 

68


 

warranty or make good obligations to Owner in respect of the Owner Furnished Equipment and Materials from and after the Make Good Commencement Date). Without limiting the foregoing, Contractor acknowledges and agrees that its obligation to perform all Work necessary to successfully pass all of the Facility Performance Tests is an absolute, unconditional, “must meet” obligation and is not subject to any limitation on liability or reduction by the payment of liquidated damages or otherwise. Upon successfully passing the Facility Performance Tests, Contractor shall be entitled to payment of its Direct Costs and Contractor’s G&A and Contractor’s Margin applicable thereto in connection with any Reimbursable Work performed after the Facility Substantial Completion Date.

15.3.5 During the Warranty Period, Owner may, or may require Contractor to, conduct a test of any item of Material, component or system that has required modification, repair or replacement under warranty. Such test shall include, where necessary or appropriate, additional Demonstration Tests or Performance Tests (as described in Exhibit R), in each case, having a scope and duration reasonably necessary to demonstrate the absence of any adverse effect.

15.3.6 If the completed Work, or any section thereof, fails to pass a test required hereunder, Owner may require such failed tests to be repeated under the same terms and conditions.

 

15.4

CORRECTION OF PERFORMANCE DEFECTS OR DEFICIENCIES.

15.4.1 At any time prior to LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable, Contractor shall advise Owner in writing of any (a) Defects or Deficiencies in or (b) defects or deficiencies in the Owner Furnished Equipment and Materials forming part of, such LNG Production System or the Facility, as applicable, that were discovered at any time or that occurred during the Performance Tests for such LNG Production System or the Facility. Contractor shall promptly commence and complete corrective measures to remedy such Defects or Deficiencies; provided, however, that, without prejudice to Contractor’s express obligations related to the Owner Furnished Equipment and Materials as set forth in the definition of “Work” such as integration and installation of Owner Furnished Equipment and Materials, Contractor has no obligation to correct defects or deficiencies in the Owner Furnished Equipment and Materials forming part of such LNG Production System or the Facility. All portions of the Work that contain Defects or Deficiencies not so corrected shall be repaired or removed from the Job Site if necessary. If Contractor fails to initiate correction of Work having such Defects or Deficiencies within seven (7) Days after discovery of such Defects or Deficiencies, Owner may correct such Work, and Owner’s costs associated with uncovering, recovering, correcting and removing Work that contains Defects or Deficiencies, as well as modifying, removing, disassembling, uncovering, rebuilding, re-engineering, replacing or covering or otherwise handling all other Work affected by such Defects or Deficiencies, shall be included in the calculation of Total Costs. If Contractor does not, within ten (10) Days of Notice from Owner, remove or repair Work (or initiate removal thereof) which has Defects or Deficiencies, Owner may, in its discretion, remove, repair, store, sell or dispose of such Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. Contractor shall promptly provide Notice to Owner in writing that such corrective measures have been completed and shall specify in such Notice the date on which the LNG Production System or the Facility will be ready for the Performance Tests to be rerun. Contractor’s obligation to correct Defects or Deficiencies includes uncovering, recovering, correcting and removing Work that contains Defects or Deficiencies, as well as modifying, removing, disassembling, uncovering, rebuilding, re-engineering, replacing or covering or otherwise handling all other Work affected by such Defects or Deficiencies or the correction thereof.

 

69


 

15.4.2 In preparation for the effort to remedy such Defects or Deficiencies discovered after LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable, Owner shall provide personnel and Contractor shall supervise and direct such personnel in the disconnection of the Work from all piping and the cleaning, freeing of liquids, solids, explosives and combustibles, toxic and asphyxiant gases and otherwise making safe for performance of the repair work. Contractor shall promptly provide Notice to Owner in writing that such corrective measures have been completed and shall specify in such Notice the date on which the LNG Production System or the Facility will be ready for the Performance Tests to be rerun. If Contractor fails to initiate correction of Work having such Defects or Deficiencies within seven (7) Days after discovery of such Defects or Deficiencies, Owner may correct such Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. If Contractor does not, within ten (10) Days of Notice from Owner, repair or remove Work (or initiate removal thereof) which has Defects or Deficiencies, Owner may, in its discretion, remove, repair, store, sell or dispose of such Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

16.

TIME FOR PERFORMANCE AND SCHEDULE.

 

16.1

TIME FOR COMPLETION.

Contractor shall cause (a) each LNG Production System Substantial Completion Date to occur no later than the relevant LNG Production System Substantial Completion Deadline, (b) the Facility Substantial Completion Date to occur no later than the Facility Substantial Completion Deadline and (c) the Final Completion Date to occur no later than the Final Completion Deadline. If an Applicable Deadline shall be actually, demonstrably and adversely affected by an excusable event hereunder including Owner Caused Delay or Force Majeure Event, and to the extent such delay could not be avoided or mitigated by Contractor (without Contractor having to incur material Non-Reimbursable Costs), then such Applicable Deadline shall be adjusted pursuant to a Change Order; provided that Contractor shall have provided proper Notice to Owner in accordance with Section 12.1.2 and that the conditions set forth in Section 12.1.3 (if applicable) are satisfied. Contractor will design (to the extent included in the Work) and integrate the Facility, supply all necessary Materials, and schedule its activities (including the scheduling of deliveries as early as practical) taking into account the possible schedule impact of reasonably foreseeable delays and take all reasonably necessary measures to mitigate the effects of any such event enumerated in the preceding sentence and to cause the occurrence of LNG Production System Substantial Completion of each LNG Production System on or before the applicable LNG Production System Substantial Completion Deadline, the occurrence of Facility Substantial Completion on or before the Facility Substantial Completion Deadline and the occurrence of Final Completion on or before the Final Completion Deadline, and to timely perform Corrective Work during the Warranty Period. No delay of an Applicable Deadline shall prejudice any right Owner may have under this Agreement to terminate this Agreement pursuant to the terms of Article 32. Owner’s requirement of correction of any Defect or Deficiency shall not under any circumstances be construed as interference with the Contractor’s performance of the Work. Contractor agrees to use commercially reasonable efforts to exhaust every reasonable repair and replacement alternative in order for the Facility to meet the requirements set forth in this Agreement, including Exhibit A.

 

70


 

16.2

FAILURE TO MITIGATE.

If, after an event that has caused Contractor to suspend or delay performance of the Work, Contractor has failed to take such action as Contractor could lawfully and reasonably initiate to remove or relieve either the cause thereof or its direct or indirect effects without incurring material Non-Reimbursable Costs, Owner may, in its sole discretion and after Notice to Contractor, initiate such reasonable measures as will be designed to remove or relieve such event or its direct or indirect effects and thereafter require Contractor to resume full or partial performance of the Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. No action by Owner pursuant to this Section 16.2 shall relieve or excuse Contractor of any of its obligations under this Agreement or constitute the basis for a Change Order.

 

16.3

RECOVERY AND ACCELERATION OF WORK.

16.3.1 In addition to Contractor’s own recovery plans, if Owner reasonably believes that Contractor will not achieve an Applicable Deadline, then Owner may provide a Notice to Contractor requiring Contractor to propose an additional recovery plan and implement it. Contractor shall be required to present a detailed recovery plan for Owner’s review and concurrence within five (5) Business Days of its receipt of the Notice described in the immediately preceding sentence, which such recovery plan shall include at a minimum the methods of expediting the Work, the additional equipment and tools to be provided and the increased manpower, technology, work shifts and supervision anticipated. Owner may suggest additional resources be added to the recovery plan but such suggestions shall in no way be deemed to limit or otherwise reduce the Contractor’s obligations and liabilities hereunder or Owner’s rights hereunder. If Owner directs Contractor to implement a recovery plan, then Contractor shall implement the recovery plan as provided in this Section 16.3.1. Contractor shall not be entitled to an increase in the Target Price in connection with any recovery plan, unless and to the extent that the recovery plan was necessitated by an event for which (a) the Contractor obtains relief through a Change Order and (b) is entitled to an adjustment to the Target Price, as applicable.

16.3.2 Notwithstanding anything contained herein to the contrary, Owner shall have the right to direct that the Work be accelerated by means of reasonable overtime, additional crews or additional shifts, notwithstanding that the progress of the Work was in accordance with the established Project Schedule. Contractor shall promptly provide to Owner for its approval a plan for such acceleration, including its recommendations for the most effective and economical acceleration, together with such information as Owner shall reasonably require to substantiate the basis of the incremental cost. Prior to the Contractor’s commencement of the accelerated Work, Owner and Contractor shall mutually agree upon the plan for acceleration and the Contractor’s acceleration cost estimate, to be set forth in a Change Order. In addition to Owner’s acceleration rights, Contractor is entitled to request an acceleration plan to be approved by Owner. Should Owner approve such plan, Owner and Contractor shall mutually agree upon the plan for acceleration and the Contractor’s acceleration cost estimate, to be set forth in a Change Order.

 

71


 

17.

SUSPENSION OR REJECTION OF THE WORK.

 

17.1

GENERAL.

17.1.1 Owner may at any time or from time to time, and for any reason, suspend performance of the Work or any portion thereof by giving a Suspension Notice to Contractor. Such suspension shall continue for the period (the “Suspension Period”) specified by Owner in the Suspension Notice. At any time after the effective date of the suspension, Owner may require Contractor to resume performance of the Work. In the event a Suspension Notice is issued by Owner under this Section 17.1.1, Contractor shall take such action as is necessary to protect, store and secure the Work, or part thereof, against any deterioration, loss or damage, and if Owner notifies Contractor of the anticipated length of such suspension, Contractor shall use reasonable efforts to delay the performance of any Work to be performed by any Subcontractor or Agent For Contractor.

17.1.2 If Owner reasonably believes that Contractor is (i) in violation of applicable Laws or any Permit and such violation has a material impact on the Facility, (ii) performing Work which has Defects or Deficiencies, is failing to correct Work which has Defects or Deficiencies in a timely manner as practicable, is failing to take the proper precautions at any time when dangerous conditions exist or (iii) otherwise in material breach of this Agreement, then Owner may, by Notice to Contractor, order Contractor to suspend performance of the Work affected by any such failure under this Section 17.1.2 by giving a Suspension Notice to Contractor. Such suspension shall continue for the Suspension Period specified in the Suspension Notice, subject to the following sentence. Upon receipt of such Suspension Notice, Contractor shall (A) suspend performance of the Work to the extent set forth in such Suspension Notice and shall not resume such Work unless and until Contractor and Owner, acting reasonably, have agreed on those actions to be taken by Contractor to eliminate or cure the cause of such Suspension Notice, and (B) take such action as is necessary to protect, store and secure the Work, or part thereof, against any deterioration, loss or damage, and if Owner notifies Contractor of the anticipated length of such suspension, Contractor shall use reasonable efforts to delay the performance of any Work to be performed by any Subcontractor or Agent For Contractor. Upon resumption of the Work, Contractor shall take all actions as and when required by such agreement with Owner.

17.1.3 Contractor may, upon prior Notice to Owner, suspend the Work in the event Owner fails to make payment of any reasonably undisputed payment to the Contractor specified in such Notice within thirty (30) days of the date such payment is due, and any such suspension shall entitle Contractor to an adjustment in the Applicable Deadlines and the Target Price, to the extent Contractor incurs Direct Costs as a direct result of such suspension.

 

17.2

COMPENSATION TO CONTRACTOR FOR SUSPENSION.

17.2.1 In the event of a suspension by Owner pursuant to Section 17.1.1, Owner shall issue a Change Order to (a) compensate Contractor for the additional Direct Costs, Contractor’s G&A and the Contractor’s Margin attributable solely to a suspension of items of Work that are documented by Contractor to the satisfaction of Owner and the Independent Engineer; (b) adjust the Target Price to reflect such additional amounts; and (c) adjust the Project Schedule for any delay in the Contractor’s performance of any Critical Path activities, which, in each case, was actually and demonstrably caused by such suspension.

 

72


 

17.2.2 All claims by Contractor for compensation under this Section 17.2 must be made monthly during the Suspension Period and within forty-five (45) Days after the end of the Suspension Period, or Contractor shall be deemed to have waived its rights for compensation with respect thereto. Amounts payable by Owner under this Article 17 shall be paid to Contractor in accordance with Article 6.

 

17.3

REJECTION OF WORK.

Owner shall have the right to inspect Materials or the Work at Contractor’s workshop and at any Subcontractor’s or Agent For Contractor’s workshop, the Job Site, or at such other places as otherwise may be appropriate, and, prior to LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable and subject to Contractor’s warranty obligations thereafter, to reject items of Materials or any portion of the Work that has Defects or Deficiencies. Owner shall specify in writing to Contractor the portion of the Materials or portion of Work that it proposes to reject and, prior to actual rejection, Contractor shall have a right to remedy any such Defects or Deficiencies to Owner’s satisfaction. Owner shall have the right to utilize any rejected portion of the Materials or the Work until such time as replacement Material is incorporated into the Facility. These rights shall not be deemed to limit Owner’s rights under Section 15.4.

 

17.4

CORRECTION OF WORK OR MATERIAL.

Contractor shall promptly correct all Materials or Work rejected by Owner as having Defects or Deficiencies observed before commencement of the Warranty Period of the applicable LNG Production System or any extension thereof, and whether or not fabricated, installed or completed. All portions of the Material or Work that contain Defects or Deficiencies not so corrected shall be repaired or removed from the Job Site if necessary, by Owner in accordance with Section 17.5. Contractor is responsible for removing Material or any portion of the Work that contain Defects or Deficiencies, as well as modifying, removing, disassembling, uncovering, rebuilding, replacing or covering or otherwise handling all other Material or Work affected by such Defects or Deficiencies or the correction thereof. These obligations shall not be deemed to limit Contractor’s obligations under Section 15.4. No action by Owner pursuant to this Section 17.4 shall relieve or excuse Contractor of any of its obligations under this Agreement or constitute the basis for a Change Order.

 

17.5

FAILURE TO CORRECT MATERIAL.

If Contractor fails to initiate correction of Materials or Work having Defects or Deficiencies in accordance with Section 17.4 within five (5) Days of Notice from Owner, Owner may correct such Materials or Work without relieving Contractor of any of its warranty obligations hereunder, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

73


 

17.6

OTHER MATERIAL OR WORK DAMAGED.

Owner shall bear the full cost of making good all Materials or any part of the Facility destroyed or damaged by reasonable removal either by Owner as provided in Section 17.5 or by Contractor, but Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

18.

LNG PRODUCTION SYSTEM COMPLETION.

 

18.1

LNG PRODUCTION SYSTEM MECHANICAL COMPLETION.

18.1.1 Upon satisfaction of the conditions set forth in this Section 18.1 for an LNG Production System, Contractor shall give Notice to Owner that LNG Production System Mechanical Completion for such LNG Production System has occurred, which shall only be when all of the following items set forth in this Section 18.1 have occurred:

(a) Contractor has certified to Owner that the Work for such LNG Production System has been designed and constructed and is ready for operation or operating in accordance with the requirements set forth in Exhibit A, applicable Laws and Permits and Owner Standards, and have performed all of its obligations under this Agreement then to be performed in relation to such LNG Production System, and the Work is free of all known Defects and Deficiencies (other than the Punch List Items);

(b) Owner has received required operations, maintenance and spare parts manuals and instruction books necessary to operate such LNG Production System in a safe, efficient and effective manner, and Contractor has completed the training program required by Article 14;

(c) Contractor has prepared and submitted for Owner’s approval, and Owner has approved, a safety transition plan for the Facility consistent with the requirements set forth in the HSSE Program;

(d) Contractor has performed all other provisions hereof and delivered all items required hereby to achieve LNG Production System Mechanical Completion of such LNG Production System in a manner reasonably satisfactory to Owner; and

(e) Contractor has delivered to Owner the LNG Production System Mechanical Completion Certificate.

18.1.2 At such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 18.1.1 has been completed with respect to an LNG Production System, Owner shall sign the LNG Production System Mechanical Completion Certificate for such LNG Production System, which shall be dated the date the final item set forth in Section 18.1.1 occurs with respect to such LNG Production System, as determined by Owner.

18.1.3 Notwithstanding anything to the contrary contained herein, Contractor shall retain care, custody, and control of an LNG Production System Handover Package until the corresponding LNG Production System Substantial Completion Date.

 

74


 

18.2

LNG PRODUCTION SYSTEM RFSU.

18.2.1 Without limitation of any scheduling requirement contained herein, Contractor shall give Owner at least one hundred eighty (180) Days’ prior Notice to the date on which Contractor expects to achieve LNG Production System RFSU for each LNG Production System. Not less than ninety (90) Days and not more than one hundred twenty (120) Days after each such Notice, Contractor shall give Owner a second Notice specifying the seven (7) Day period during which Contractor expects to achieve LNG Production System RFSU for the applicable LNG Production System. At such time as each LNG Production System achieves LNG Production System RFSU, Contractor shall certify to Owner in the form of an LNG Production System RFSU Certificate that all requirements under this Agreement for LNG Production System RFSU with respect to the applicable LNG Production System have been satisfied. Each LNG Production System RFSU Certificate shall be accompanied by other supporting documentation as may be required under this Agreement to establish, to Owner’s reasonable satisfaction, that the requirements for LNG Production System RFSU have been met, including that Owner has received from Contractor all final Permits relating to such LNG Production System and required to be obtained by Contractor and, if final Permits are not available, all temporary Permits to enable Owner to operate such LNG Production System uninterrupted until such time as such final Permits are obtained. Owner shall by Notice to Contractor confirm whether it accepts or rejects each LNG Production System RFSU Certificate within twenty-four (24) hours following Owner’s receipt thereof. Acceptance of LNG Production System RFSU with respect to an LNG Production System shall be evidenced by Owner’s signature on the applicable LNG Production System RFSU Certificate. The date of LNG Production System RFSU shall be based upon, and the date of Owner’s acceptance of LNG Production System RFSU shall be deemed to have occurred on, the date listed on the applicable LNG Production System RFSU Certificate; provided that all requirements under this Agreement for LNG Production System RFSU were achieved on such date listed on the applicable LNG Production System RFSU Certificate. If Owner does not agree that LNG Production System RFSU has occurred with respect to a particular LNG Production System, then Owner shall state the basis for its rejection in reasonable detail in such Notice. If the Parties do not mutually agree on when and if LNG Production System RFSU with respect to an LNG Production System has occurred, the Parties shall thereupon promptly and in good faith confer and make all reasonable efforts to resolve such issue. In the event such issue is not resolved within two (2) Business Days of the delivery by Owner of its Notice to Contractor, the Parties shall resolve such Dispute in accordance with Article 36. Owner’s acceptance of LNG Production System RFSU with respect to an LNG Production System shall not relieve Contractor of any of its obligations to perform the Work in accordance with the requirements of this Agreement.

18.2.2 After Owner has accepted the System Turnover Packages, LNG Production System Mechanical Completion has occurred, and the start-up and Pre-Commissioning test reports have been provided to Owner for one (1) or more LNG Production Systems and Contractor has resolved Owner and the Contractor’s lists of Defects or Deficiencies for such LNG Production System(s) (other than the Punch List Items), if any, Contractor shall schedule the cooldown of Tank Three or Tank Four, as applicable (each an “LNG Storage Tank Cooldown”). Contractor shall provide Owner with Notice at least one hundred eighty (180) Days’ prior to the date on which Contractor expects LNG Storage Tank Cooldown to occur and shall specify in such Notice the amount of Feed Gas required for LNG Storage Tank Cooldown. Not less than ninety (90) Days and not more than one hundred twenty (120) Days after such Notice, Contractor shall give Owner a second Notice specifying the seven (7) Day period during which Contractor expects LNG Storage Tank Cooldown to occur and confirming the amount of Feed Gas required for LNG Storage Tank Cooldown.

 

75


 

18.3

LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION.

18.3.1 Upon compliance with all other conditions set forth in this Section 18.3, Contractor shall give Notice to Owner that LNG Production System Substantial Completion of an LNG Production System has occurred, which shall only be when all of the following items set forth in this Section 18.3 have occurred, unless Owner agrees in writing to waive any such requirements:

(a) all of the conditions for LNG Production System Mechanical Completion of such LNG Production System set forth in Section 18.1 have been met, and Owner has received and accepted the LNG Production System RFSU Certificate for such LNG Production System in accordance with Section 18.2;

(b) Owner has received the relevant System Turnover Packages demonstrating that Contractor has successfully completed all of the Pre-Commissioning and Commissioning of such LNG Production System;

(c) such LNG Production System is ready for normal, continuous and safe operation with the complement of personnel contemplated in Exhibit Q, and Contractor has corrected all Defects and Deficiencies (other than the Punch List Items);

(d) the Performance Tests for such LNG Production System have been satisfactorily completed in accordance with Exhibit R; and

(e) Contractor has delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 18.3.1.

18.3.2 At such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 18.3.1 has been completed with respect to an LNG Production System, Owner shall issue to Contractor a certificate stating the LNG Production System Substantial Completion Date for such LNG Production System, which date shall be the date that Contractor delivered to Owner a certificate certifying the satisfaction of each of the items in Section 18.3.1.

 

19.

FACILITY COMPLETION.

 

19.1

FACILITY MECHANICAL COMPLETION.

19.1.1 Upon satisfaction of the conditions set forth in this Section 19.1, Contractor shall give Notice to Owner that Facility Mechanical Completion has occurred, which shall only be when all of the following items set forth in this Section 19.1 have occurred:

(a) all the conditions for LNG Production System Mechanical Completion for all the LNG Production Systems set forth in Section 18.1 have been met, and Owner has received and accepted the LNG Production System RFSU Certificate for all of the LNG Production Systems in accordance with Section 18.2;

 

76


 

(b) Contractor has certified to Owner that the Facility has been designed (to the extent included in the Work), integrated and constructed and is ready for operation or operating in accordance with the requirements set forth in Exhibit A, applicable Laws and Permits and Owner Standards, and has performed all of its obligations under this Agreement then to be performed, and the Work is free of all Defects and Deficiencies (other than the Punch List Items);

(c) Owner has received from Contractor all final Permits required to be obtained by Contractor and, if final Permits are not available, all temporary Permits to enable Owner to operate the Facility uninterrupted until such time as such final Permits are obtained;

(d) Contractor has performed all other provisions hereof and delivered all items required hereby to achieve Facility Mechanical Completion in a manner reasonably satisfactory to Owner; and

(e) Contractor has delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 19.1.1.

19.1.2 At such time as Owner and the Independent Engineer have confirmed that each of the foregoing matters have been completed, Owner shall issue to Contractor a certificate stating the Facility Mechanical Completion Date. Facility Mechanical Completion shall be deemed to occur on the date the final item set forth in Section 19.1.1 occurs, as determined by Owner, and not the date such certification is received.

 

19.2

FACILITY SUBSTANTIAL COMPLETION.

19.2.1 Upon compliance with all other conditions set forth in this Section 19.2.1, Contractor shall give Notice to Owner that Facility Substantial Completion has occurred, which shall only be when all of the following items set forth in this Section 19.2.1 have occurred:

(a) all of the conditions for Facility Mechanical Completion set forth in Section 19.1 have been met, and Owner has received and accepted the LNG Production System RFSU Certificate for each LNG Production System in accordance with Section 18.2;

(b) all of the conditions for LNG Production System Substantial Completion set forth in Section 18.3 have been met for all of the LNG Production Systems;

(c) Contractor has made available to Owner at the Job Site all special tools and Spare Parts in accordance with Section 3.9.1 (any reorders to be a Punch List Items in accordance with Section 19.5);

(d) Contractor has successfully completed all of the Demonstration Tests for the Facility, as verified by reports delivered by Contractor to Owner;

(e) Owner has received the System Turnover Packages demonstrating that Contractor has successfully completed all of the Commissioning for the Facility;

 

77


 

(f) the Facility is ready for normal, continuous and safe operation with the complement of personnel contemplated in Exhibit Q, and Contractor has corrected all Defects and Deficiencies (other than the Punch List Items);

(g) Contractor has completed the training program required by Article 14;

(h) Contractor has performed all other provisions hereof required for normal, continuous and safe operation and delivered all items required hereby (except any Punch List Items or other obligations of Contractor not intended to be fully performed at Facility Substantial Completion) required by this Agreement;

(i) (A) the Performance Tests for the Facility have been satisfactorily completed in accordance with Exhibit R;

(j) Contractor has paid all amounts to Owner then due and payable hereunder, or Owner has elected to set-off such amounts against any payment that may be owed by Owner to Contractor;

(k) Contractor has provided Owner a complete list of the Punch List Items;

(l) Contractor has prepared, and submitted to Owner’s Representative the operation and maintenance manuals, operating instructions, system checklists and/or procedures required to be provided by Contractor under Exhibit J in the English language in sufficient detail for Owner to operate, maintain, dismantle, reassemble, adjust and repair the Facility; and

(m) Contractor has delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 19.2.1.

19.2.2 The Facility shall be fully taken over by Owner at such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 19.2.1 has been completed and Owner issues to Contractor a certificate stating the Facility Substantial Completion Date which shall be the date the final item set forth in Section 19.2.1 occurs with respect to the Facility, as determined by Owner, and not the date the certification is received.

19.2.3 For the avoidance of doubt, the foregoing conditions to Facility Substantial Completion are independent of Contractor’s obligations under the Phase 1 Agreement.

 

19.3

READY FOR SHIP LOADING.

Without limiting the foregoing or any other scheduling requirements contained herein, Contractor shall provide Owner (a) at least one hundred eighty (180) Days’ prior Notice of the day on which Contractor expects to be ready for Owner or its Affiliate to perform the Loading Rate Test, and (b) a second Notice specifying the date on which Contractor expects to be ready for the Loading Rate Test, which second Notice shall be given no later than sixty (60) Days prior to such date. Owner shall cause an LNG Tanker to be available, after the date in such second Notice; provided that Owner is not required to schedule such LNG Tanker until (a) there is sufficient LNG in storage in the LNG Storage Tanks to perform the Loading Rate Test and (b) Owner has the

 

78


 

ability and an economic reason to export such LNG; provided, further, that if Owner’s decision not to schedule an LNG Tanker adversely impacts commissioning or testing activities, then Contractor shall be entitled to a Change Order for such decision if and to the extent it meets the requirements for an Owner Caused Delay. Owner shall give Contractor fourteen (14) Days prior written notice of a five (5) Day period in which the LNG Tanker will be available for the Loading Rate Test. Contractor shall assist Owner in identifying prospective LNG Tanker operators to conduct assurance and vetting of the marine terminal, and shall provide reasonable access to the Job Site to such operators and to other LNG Tanker operators who are anticipated to use the Facility to conduct such assurance and vetting activities.

 

19.4

FINAL COMPLETION.

19.4.1 Final Completion of the Facility shall occur no later than the Final Completion Deadline. In order to achieve Final Completion, Contractor must have:

(a) met all the conditions for Facility Substantial Completion set forth in Section19.2;

(b) completed a Facility final clean-up including removal from the Job Site of all construction debris, bulk construction materials, storage trailers, temporary facilities, scaffolding, temporary protection and other impediments that would interfere with the normal operation and maintenance of the Facility, and Contractor has delivered the Facility in a clean condition satisfactory to Owner in accordance with the procedures set forth in Exhibit A;

(c) completed all Punch List Items, which Punch List Items shall be promptly completed upon receipt of such Material(s) or other event(s) and corrected all Defects and Deficiencies identified by Owner during the Performance Tests which Owner has decided do not require completion and re-running of the Performance Tests, and Owner must have accepted such corrections in writing;

(d) delivered to Owner all electronic files in the format designated by Owner, all Drawings and Specifications (including red-lined “as-built” drawings of such LNG Production System), test data and other technical information relating to such LNG Production System and required hereunder for Owner to operate and maintain such LNG Production System;

(e) delivered to Owner all as-built operations, maintenance and spare parts manuals and instruction books required to be delivered by Contractor that are necessary to operate the Facility in a safe, efficient and effective manner, and Contractor has completed the training program required by Article 14;

(f) delivered to Owner all electronic files in the format designated by Owner, all Drawings and Specifications (except final “as-built” drawings of the Facility, but including red-lined “as-built” drawings of the Facility), test data and other technical information required hereunder for Owner to operate and maintain the Facility;

(g) delivered to Owner final “as-built” drawings for the Facility as required by Section 3.8.43 and meeting the requirements of Exhibit J;

 

79


 

(h) removed all the Contractor’s, Subcontractors’, and Agent For Contractors’ personnel, supplies, equipment, waste materials, rubbish and temporary facilities from the Job Site (unless otherwise requested by Owner);

(i) delivered evidence satisfactory to Owner, including a Payment Status Affidavit from Contractor and all Major Subcontractors in the form of Exhibit F-15 and Exhibit F-16, respectively, and a final and unconditional release and waiver of liens from Contractor and all Major Subcontractors in the form of Exhibit F-3 and Exhibit F-4, respectively, that all claims, liens, security interests or encumbrances in the nature of mechanics’, labor or materialmen’s liens (if applicable) arising out of or in connection with the Job Site, Facility (or any portion thereof), any Materials, any land or improvements pertinent thereto or the performance by Contractor or any Major Subcontractor of the Work have been satisfied or discharged;

(j) performed all other provisions hereof and delivered all items required hereby (except any warranty or other obligation of Contractor not intended to be fully performed at Final Completion) in a manner satisfactory to Owner;

(k) paid all undisputed amounts to Owner then due and payable hereunder; and

(l) delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 19.4.1.

19.4.2 At such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 19.4.1 has been completed, Owner shall issue a Final Completion certificate. Notwithstanding the foregoing, nothing contained in this Section 19.4 shall relieve Contractor from performing any obligations remaining under this Agreement after Final Completion, including any of its warranty obligations hereunder.

 

19.5

PUNCH LIST ITEMS.

Notwithstanding anything to the contrary contained herein, at Owner’s sole discretion, Owner may approve the completion of Punch List Items after Final Completion. If Contractor does not promptly complete any remaining Punch List Item, Owner shall have the right to complete such item and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. Notwithstanding anything to the contrary contained herein, however, if the completion of any Punch List Items requires that an LNG Production System or the Facility be shut down or its output curtailed, Owner shall have the option of completing such Punch List Items itself, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

20.

WARRANTY FOR DEFECTS.

 

20.1

IN GENERAL.

20.1.1 As further described herein, Contractor shall repair or replace all Defects and Deficiencies prior to the commencement of the Warranty Period. Upon commencement of the Warranty Period, Contractor shall be required to perform all Corrective Work (defined below).

 

80


 

20.1.2 During the Warranty Period, Contractor shall, as soon as practicable, complete any Work that is outstanding at Final Completion and shall be responsible for performing Corrective Work which may appear or occur during the Warranty Period or any extension thereof.

20.1.3 During the Warranty Period and subject to Section 20.1.4, Contractor shall make good the Defects or Deficiencies in the Work promptly and on an expedited basis whether by repair, replacement or otherwise (the “Corrective Work”). In the event Contractor utilizes spare parts owned by Owner in the course of performing the Corrective Work or Work as provided in Section 20.1.4, Contractor shall supply Owner with new spare parts equivalent in quality and quantity to all such spare parts used by Contractor as soon as possible following the utilization of such spare parts.

20.1.4 If Contractor is obligated to repair, replace or renew a Serial Defect, Contractor shall undertake a technical analysis of the problem and correct the “root cause” unless Contractor can demonstrate to Owner’s satisfaction that there is not a risk of the reoccurrence of such problem. Contractor’s obligations under this Article 20 shall not be impaired or otherwise adversely affected by any actual or possible legal obligation or duty of any Subcontractor or Agent For Contractor, in each case, to Contractor or Owner concerning any Defect or Deficiency. No such correction or cure, as the case may be, shall be considered complete until Owner shall have reviewed and approved such remedial work in accordance with this Agreement.

20.1.5 Contractor shall have no obligation hereunder to correct Defects and Deficiencies in the Work relating to site preparation activities in the area described in Exhibit A.

 

20.2

SPECIFIC WARRANTIES.

In particular, Contractor warrants to Owner that:

20.2.1 Contractor shall perform the Work in full compliance with the terms and conditions set forth herein;

20.2.2 the Materials and the Work shall be designed, manufactured, engineered, constructed, completed, pre-commissioned, commissioned, tested and delivered in accordance with this Agreement;

20.2.3 the Materials and the Work shall be designed, manufactured, engineered, constructed, completed, tested and delivered, in a workmanlike manner and in accordance with this Agreement, Owner Standards, all Permits and approvals of Government Authorities, Applicable Codes and Standards and all applicable Laws;

20.2.4 the Work, including all Materials and each component thereof (a) shall conform to the specifications and descriptions set forth herein, (b) shall be new, complete, and of suitable grade for the intended function and use in accordance with this Agreement, (c) shall be free from defects (including latent defects) in design, material and workmanship, and (d) shall meet the requirements set forth in Exhibit A and the Agent For Contracts;

20.2.5 the Materials, or any component of Materials, shall be composed and made of only proven technology, of a type in commercial operation at the Effective Date; provided that Owner’s agreement for Contractor to use any Materials not in compliance with this Section 20.2.5 shall not relieve Contractor of any of its obligations under this Agreement;

 

81


 

20.2.6 if, prior to the expiration of the Warranty Period, two (2) or more of the same components of the Work experience a Defect of an identical or nearly identical nature that causes or could reasonably be expected to cause an outage or derating of the Facility (herein, a “Serial Defect”), then Contractor shall examine the cause of the Serial Defect and (i) undertake technical analysis of the underlying problem in order to determine (A) the root cause of such Serial Defect and (B) the repairs or replacements that may be required to avoid future occurrences of such Serial Defect, (ii) prepare and provide to Owner a written report setting forth the results of such analysis, (iii) promptly redesign if necessary and repair or replace any Materials, as necessary, and (iv) extend the Warranty Period for that portion of the Work that Contractor redesigned, repaired or replaced for an additional period of [***] months. Such warranty extension for Serial Defects is in lieu of and not in addition to the extension of the Warranty Period contemplated in Section 20.4.2.

20.2.7 Contractor shall, at all times during the Warranty Period, maintain sufficient personnel at Contractor’s offices to respond promptly to Owner’s request for diagnostic or warranty work. At any time during the Warranty Period, Contractor shall promptly and on an expedited basis perform such tests, inspections or other diagnostic services as may be reasonably requested by Owner. In the event that such diagnostic services reveal any Work not conforming to the Contractor’s Warranties, any and all such Work shall be corrected immediately as Corrective Work (the warranties set forth in Sections 20.2.1 to 20.2.7 inclusively are referred to collectively as the “Warranties”). The Warranties shall not include work performed under the Owner Contracts; and

20.2.8 Contractor shall, in the course of correcting any Defects or Deficiencies, do so (a) in good faith coordination with Owner’s schedule of operations so as to minimize any adverse effect on the operations of the Facility and (b) in accordance with the Warranty procedures set forth in this Article 20.

 

20.3

NOTICE OF DEFECTS OR DEFICIENCIES.

If any Defects, Deficiencies or resulting damage to the Work appear or arise from notifications by manufacturers of Material, Owner shall promptly notify Contractor of such Defects, Deficiency or damage, and Contractor shall perform the necessary repairs or replacements in accordance with its Warranty obligations. Owner shall be entitled to determine the existence of any Defects, Deficiencies or damage.

 

20.4

EXTENSION OF WARRANTY PERIOD.

20.4.1 The provisions of this Article 20 shall apply to all replacements or repairs carried out by Contractor as if the replacements and repairs had been taken over on the date they were completed. All Corrective Work shall be performed subject to the same terms and conditions under this Agreement as the original Work is required to be performed. Any change to parts or Materials that would alter the requirements of this Agreement or any Agent For Contract may be made only with prior written approval of Owner.

 

82


 

20.4.2 The Warranty Period for the Work or portion thereof that Contractor has replaced or repaired shall be extended by a period of [***] months from the date the replacement or repair is completed (and for successive periods of [***] months in the event of any Defect or Deficiency associated with any such replacement or repair), but in no event shall the Warranty Period extend beyond [***] months following Facility Substantial Completion.

 

20.5

FAILURE TO REMEDY DEFECTS.

If Contractor fails to commence any Corrective Work within a reasonable period of time not to exceed five (5) Days after receipt of Owner’s written notice to Contractor identifying and describing with reasonable specificity that portion of Work that has a Defect or Deficiency, or does not complete such Corrective Work on an expedited basis, Owner may, in its sole discretion and in addition to any other remedies that it has under this Agreement, proceed to do the Work and, subject to Section 16.2, notify Contractor of its intention to do so, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

20.6

REMOVAL AND OWNERSHIP OF DEFECTIVE WORK.

If the Defects, Deficiencies or resultant damage is such that it cannot be remedied expeditiously on the Job Site, Contractor may, with the prior written consent of Owner’s Representative or Owner, remove from the Job Site for the purposes of repair or replacement of any part of the Work which is defective, deficient or damaged.

 

20.7

FURTHER TESTS.

If the repair or replacement of any equipment or components of Work is such that it may affect the operation of the Work or any part thereof, then Owner may require that tests of such equipment or components or any affected part of the Work thereof be conducted by Contractor and repeated to the extent reasonably necessary. Such requirement shall be made by Notice within thirty (30) Days after the Defect or Deficiency is remedied. Such tests shall verify that the equipment or component or any affected part of the Work thereof, as the case may be, is at the same level of performance as existed prior to the need for repair or replacement.

 

20.8

RIGHT OF ACCESS.

Until the expiration of the Warranty Period, but only to the extent required to perform its obligations hereunder, Contractor shall have the right of reasonable access to all parts of the Work and to records of the working and performance of the Work, except as may be inconsistent with any reasonable security or safety restrictions of the Owner. Such right of access shall be undertaken so as to minimize interference with the operation of the Facility. Access shall be granted to any duly authorized representative of Contractor whose name has been communicated in writing to Owner and who agrees to be bound by Owner Protocols and the confidentiality provisions of this Agreement in connection with such access. The Parties shall schedule corrections, repairs or replacements as necessary so as to minimize disruptions to the operation of the Facility.

 

83


 

20.9

SUBCONTRACTOR AND AGENT FOR CONTRACTOR WARRANTIES.

20.9.1 Contractor shall, for the protection of Contractor and Owner, use reasonable efforts to obtain from the Subcontractors such guarantees and warranties with respect to Work performed that are equal to or exceed those set forth in this Article 20 as applicable to their respective scopes of work and shall be made available and in the name of Owner and assignable to the Lenders to the full extent of the terms thereof. Subject to Section 23.1.4, Contractor shall enforce all Subcontractor and Agent For Contractor warranties in accordance with their terms so as to minimize the amount of Work Contractor may be required to perform to correct any Defect or Deficiency in the Subcontractors’ or Agent For Contractors’ work. Owner shall be an express third-party beneficiary of all such guarantees and warranties. To the extent available, Owner shall have the right to require Contractor to secure additional warranty or extended guarantee protection pursuant to a Change Order. Upon the earlier of the date of Final Completion or termination of this Agreement, Contractor shall deliver to Owner copies of all relevant contracts providing for such guarantees and warranties.

20.9.2 Upon the earlier of Final Completion or termination of this Agreement, Contractor shall assign to Owner all warranties received by it from Subcontractors that are not otherwise issued in Owner’s name. Such assignment of warranties to Owner must also allow Owner to further assign such warranties. However, in the event that Owner makes any warranty claim against Contractor with respect to any portion of the Work supplied in whole or in part by any Subcontractor, and Contractor fulfills its obligations with respect to such claim by Owner, Contractor shall be entitled to enforce for its own benefit any warranty given by such Subcontractor with respect to such portion of the Work.

 

20.10

NO IMPLIED WARRANTIES.

EXCEPT FOR THE EXPRESS WARRANTIES SET FORTH IN THIS ARTICLE 20 (INCLUDING THE “WARRANTIES”), CONTRACTOR DOES NOT MAKE ANY OTHER WARRANTIES, WHETHER STATUTORY, EXPRESS OR IMPLIED (INCLUDING ANY IMPLIED WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE AND ALL WARRANTIES ARISING FROM COURSE OF DEALING OR USAGE OF TRADE). OWNER’S EXCLUSIVE REMEDIES AND CONTRACTOR’S ONLY OBLIGATIONS ARISING OUT OF OR IN CONNECTION WITH DEFECTIVE WORK (PATENT, LATENT OR OTHERWISE), WHETHER BASED IN CONTRACT, IN TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY), OR OTHERWISE, ARE SET FORTH IN THIS ARTICLE 20. ALL SUCH OTHER WARRANTIES, CONDITIONS AND REPRESENTATIONS ARE HEREBY DISCLAIMED. THE FOREGOING IS NOT INTENDED TO DISCLAIM ANY OTHER OBLIGATIONS OF CONTRACTOR WHICH ARE UNRELATED TO DEFECTS OR DEFICIENCIES IN THE WORK AS EXPRESSLY SET FORTH HEREIN.

 

20.11

REPAIRS AND TESTING BY OWNER.

20.11.1 During the Warranty Period, without prior notice to Contractor Owner, by itself or through its Affiliate, shall be permitted to (a) make repairs or replacements on the Materials or the Facility and (b) adjust or test the Materials or the Facility as outlined in the operations and maintenance manuals provided by Contractor or any Subcontractor or Agent For Contractor.

 

84


 

20.11.2 In the event of an emergency and if, in the judgment of Owner, the delay that would result from giving prior notice to Contractor could cause serious loss or damage which could be prevented by immediate action, any action (including correction of Defects) may be taken by Owner or a third party chosen by Owner, without giving prior notice to Contractor. In the event such action is taken by Owner, Contractor shall be promptly notified after Corrective Work is implemented, and shall assist whenever and wherever possible in making the necessary corrections. All such warranties obtained shall be in addition to, and shall not alter, the warranties of Contractor. Upon Owner’s request, Contractor shall use all reasonable efforts to force Subcontractors or Agent For Contractors to honor warranties including filing suit to enforce same.

 

20.12

SURVIVAL OF WARRANTIES.

Prior to the end of the Warranty Period, the provisions of this Article 20 shall survive the expiration or earlier termination of this Agreement. The Warranties made herein shall be for the benefit of Owner and its successors and permitted assigns and the respective successors and permitted assigns of any of them, and are fully transferable and assignable. Owner may assign its rights to the Warranties during the Warranty Period to any Affiliate, Lender, or any Person acquiring a substantial ownership interest in the Facility without the consent of Contractor.

 

21.

LIABILITY.

 

21.1

TOTAL LIABILITY CAP.

Notwithstanding anything to the contrary contained herein, Contractor’s cumulative aggregate liability hereunder, whether in contract, warranty (including in respect of Corrective Work), tort, (including negligence whether sole or concurrent), strict liability, products liability, professional liability, indemnity, contribution, statute, at law, in equity, or any other cause of action, shall not exceed an amount equal to [***]; provided that, notwithstanding the foregoing, the limitation of liability set forth in this Section 21.1 shall not: (a) apply in the event of Abandonment of the Project by Contractor; (b) apply to Contractor’s indemnification obligations under this Agreement with respect to: (i) any claims brought by Third Parties (for purposes of this Section 21.1 “Third Parties” shall include Owner’s and its Affiliate’s employees) for bodily injury, death or property damage as described in Section 30.1.2(b); or (ii) costs and expenses incurred by Contractor to fulfill those express indemnity obligations set forth in Sections 5.1.2, 6.4.2, 30.1.1, 30.1.2, 30.1.3 and 40.4.2; (c) apply to Contractor’s obligation to deliver to Owner full legal title to and ownership of all or any portion of the Work as required under this Agreement; (d) include the payment of insurance proceeds under any Project-specific insurance policy obtained by Contractor; (e) include any amount in respect of any Non-Reimbursable Cost; (f) apply in the event of the Gross Negligence or Willful Misconduct of Senior Supervisory Personnel; (g) apply to limit Contractor’s costs incurred to achieve the “make good” obligations under Section 15.3.4; or (h) take into account or otherwise be affected by any reduction in Contractor’s entitlement to the payment of or forfeiture of the Margin Percentage.

 

85


 

21.2

NO CONSEQUENTIAL DAMAGES.

Notwithstanding anything to the contrary contained herein, except with respect to (a) any claims for bodily injury, death or physical damage to property of Third Parties for which Contractor owes an indemnity obligation as described in Section 30.1.2(b) (notwithstanding Section 30.1.2(b), with respect to bodily injuries, “Third Parties” shall exclude Owner’s employees for purposes of this Section 21.2), (b) any damages resulting from the Gross Negligence or Willful Misconduct of Senior Supervisory Personnel, (c) any liquidated damages which may be payable as set forth in Article 22, and (d) any damages resulting from Contractor’s breach of Article 27, Contractor, its agents and Affiliates (including the Contractor Guarantors), workers, Subcontractors and suppliers and the employees of each shall not be liable for, and Owner hereby waives, any incidental, indirect, punitive or consequential damages, loss of or default under business contracts, lost revenues or for loss of profit, product, revenue, contract or use arising out of or in connection with the performance of the Work or this Agreement whether or not any such liability is claimed in contract, statute, equity, tort or otherwise and shall apply irrespective of negligence. In addition, except with respect to (a) Third Party claims for which Owner has agreed to indemnify Contractor in accordance with Section 30.2, and (b) Owner’s breach of its confidentiality obligations under Article 27, Owner shall have no liability for, and Contractor hereby waives, releases, defends, indemnifies and holds harmless any incidental, indirect, punitive or consequential damages (which includes loss of or default under business contracts, lost revenues or lost profits but excluding those amounts payable by Owner to Contractor in the event of a termination for default pursuant to Section 31.5 or for convenience pursuant to Article 32) arising out of or in connection with this Agreement.

 

21.3

JOINT AND SEVERAL LIABILITY.

The Parties acknowledge and agree that each Contractor Guarantor shall be jointly and severally liable to Owner for each and every obligation and liability of Contractor under this Agreement, including any liabilities arising out of or relating to the alleged or actual delay, fault, default, non-performance or inadequate performance of Contractor, to the extent provided in each Contractor Guarantee. Without limiting the generality of the foregoing, Owner shall be entitled to make any claim for any damages or liability arising under this Agreement against any or all of the Contractor and the Contractor Guarantors.

 

22.

PERFORMANCE TESTS; LIQUIDATED DAMAGES.

 

22.1

PERFORMANCE TESTS.

The Performance Tests are described in Exhibit R.

 

22.2

SCHEDULE DELAY LIQUIDATED DAMAGES FOR FAILURE TO ACHIEVE LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION OR FACILITY SUBSTANTIAL BY AN APPLICABLE DEADLINE.

22.2.1 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the LPS5 Substantial Completion Date has not occurred on or before the date that is [***] days after the LPS5 Substantial Completion Deadline, Contractor shall:

 

86


 

(a) pay LPS5 Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the LPS5 Substantial Completion Date and (ii) the Day on which Contractor has paid LPS5 Schedule Delay Liquidated Damages in an amount equal to the LPS5 Schedule Delay Liquidated Damages Cap, in the following amounts:

(1) for the period commencing on the date that is [***] days after the LPS5 Substantial Completion Deadline and ending on the date that is [***] days after the LPS5 Substantial Completion Deadline, [***] per day;

(2) for the period commencing on the date that is [***] days after the LPS5 Substantial Completion Deadline and ending on the date that is [***] days after the LPS5 Substantial Completion Deadline, [***] per day;

(3) for the period commencing on the date that is [***] days after the LPS5 Substantial Completion Deadline and ending on the date that is [***] days after the LPS5 Substantial Completion Deadline, [***] per day;

(4) for the period commencing on the date that is [***] days after the LPS5 Substantial Completion Deadline and ending on the date that is [***] days after the LPS5 Substantial Completion Deadline, [***] per day.

22.2.2 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the LPS6 Substantial Completion Date has not occurred on or before the date that is [***] days after the LPS6 Substantial Completion Deadline, Contractor shall pay LPS6 Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the LPS6 Substantial Completion Date and (ii) the Day on which Contractor has paid LPS6 Schedule Delay Liquidated Damages in an amount equal to the LPS6 Schedule Delay Liquidated Damages Cap, in the following amounts:

(a) for the period commencing on the date that is [***] days after the LPS6 Substantial Completion Deadline and ending on the date that is [***] days after the LPS6 Substantial Completion Deadline, [***] per day;

(b) for the period commencing on the date that is [***] days after the LPS6 Substantial Completion Deadline and ending on the date that is [***] days after the LPS6 Substantial Completion Deadline, [***] per day;

(c) for the period commencing on the date that is [***] days after the LPS6 Substantial Completion Deadline and ending on the date that is [***] days after the LPS6 Substantial Completion Deadline, [***] per day; and

 

87


 

(d) for the period commencing on the date that is [***] days after the LPS6 Substantial Completion Deadline and ending on the date that is [***] days after the LPS6 Substantial Completion Deadline, [***] per day.

22.2.3 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the Facility Substantial Completion Date has not occurred on or before the date that is [***] days after the Facility Substantial Completion Deadline, Contractor shall pay Facility Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the Facility Substantial Completion Date and (ii) the Day on which Contractor has paid Facility Schedule Delay Liquidated Damages in an amount equal to the Facility Schedule Delay Liquidated Damages Cap, in the following amounts:

(a) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] days after the Facility Substantial Completion Deadline, [***] per day;

(b) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] days after the Facility Substantial Completion Deadline, [***] per day;

(c) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] days after the Facility Substantial Completion Deadline, [***] per day; and

(d) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] days after the Facility Substantial Completion Deadline, [***] per day.

22.2.4 Except as set forth in Section 31.2, Contractor’s payment of Schedule Delay Liquidated Damages as set forth in Sections 22.2.1 through 3, and the other remedies set forth in Section 22.2.1(b) and (c), shall be the sole and exclusive remedy of Owner for Contractor’s failure to achieve the LPS5 Substantial Completion Date on or before the LPS5 Substantial Completion Deadline, the LPS6 Substantial Completion Date on or before the LPS6 Substantial Completion Deadline or the Facility Substantial Completion Date on or before the Facility Substantial Completion Deadline.

22.2.5 In the event that the Work fails to achieve any of the requirements provided in this Agreement required to achieve LNG Production System Substantial Completion or Facility Substantial Completion, as evidenced by the Performance Test results, by the LNG Production System Substantial Completion Deadline for an LNG Production System or the Facility Substantial Completion Deadline, as applicable, then LNG Production System Substantial Completion of such LNG Production System or Facility Substantial Completion, as applicable, shall not occur.

 

88


 

22.3

LIQUIDATED DAMAGES CAP.

22.3.1 The total amount of Contractor’s obligations to pay Schedule Delay Liquidated Damages pursuant to Section 22.2 shall not exceed the following amounts:

(a) LPS5 Schedule Delay Liquidated Damages shall not exceed [***] (the “LPS5 Schedule Delay Liquidated Damages Cap”);

(b) LPS6 Schedule Delay Liquidated Damages shall not exceed [***] (the “LPS6 Schedule Delay Liquidated Damages Cap”); and

(c) Facility Schedule Delay Liquidated Damages shall not exceed [***] (the “Facility Schedule Delay Liquidated Damages Cap”).

22.3.2 The total amount of Contractor’s obligations to pay Schedule Delay Liquidated Damages hereunder shall not exceed [***] in the aggregate.

22.3.3 If at any time Contractor is as a result of the operation of Section 22.3.1 or Section 22.3.2 no longer liable hereunder to pay Schedule Delay Liquidated Damages, then Owner may terminate this Agreement in accordance with Sections 31.1.17 and 31.4 or continue to permit Contractor to progress the Work in accordance with the requirements of this Agreement.

 

22.4

PAYMENT.

22.4.1 Schedule Delay Liquidated Damages shall accrue daily hereunder and shall be payable by Contractor monthly, no later than the fifth (5th) Business Day of the immediately following month.

22.4.2 All liquidated damage amounts required to be paid by Contractor under this Article 22 shall cease accruing upon a termination of this Agreement.

 

22.5

LIQUIDATED DAMAGES REASONABLE.

The Parties acknowledge and agree that actual damages for Contractor’s failure to successfully pass the Performance Tests and achieve the relevant milestones by the Applicable Deadlines are difficult to determine and that the liquidated damages set forth herein are reasonable and appropriate measures of the damages for such failure, are apportioned in a fair and appropriate manner including with respect to any lump-sum liquidated damages that may be payable in respect of any single day of delay, and do not represent a penalty. If Contractor, any Contractor Guarantor or anyone on its behalf successfully challenges the applicable rate of any liquidated damages, Contractor specifically agrees to pay Owner all actual damages incurred by Owner in connection with such breach, including any and all consequential damages (such as loss of profits and revenues, business interruption, loss of opportunity and use) and all costs incurred by Owner in proving the same, without regard to any limitations whatsoever set forth herein.

 

89


 

22.6

EFFECT ON OTHER PROVISIONS.

The provisions of this Article 22 shall affect neither Contractor’s obligations to complete any other requirement herein which is unrelated to schedule nor Owner’s right to withhold amounts retained under Section 6.8 hereof.

 

23.

SUBCONTRACTORS.

23.1.1 Attached as Exhibit H and Exhibit O is a list of names of potential Major Subcontractors. Contractor may submit to Owner the names and qualifications and recommendations of additional Major Subcontractors that it desires to include in Exhibit H or Exhibit O. Any additions or changes to Exhibit H or Exhibit O shall be decided solely by Owner within a reasonable time following the submission of all necessary supporting documentation by Contractor. At the request of Owner, the Lenders or Owner’s title insurance providers, Contractor shall provide an affidavit of all Major Subcontractors, in a form acceptable to Owner, the Lenders or Owner’s title insurance providers, as applicable. All Major Subcontractors will be selected from Exhibit H or Exhibit O as supplemented from time to time in accordance with this Section 23.1.1. Contractor shall not enter into Major Subcontracts with any Person not listed in Exhibit H or Exhibit O without the prior written approval of Owner. Contractor shall issue all Subcontracts in accordance with the terms of this Agreement. Approval by Owner of any Subcontractor or its receipt or review of any Subcontract shall not (a) relieve Contractor of any of its obligations under this Agreement or (b) constitute any acceptance of the Work undertaken by such Person. No Subcontract shall bind or purport to bind Owner.

23.1.2 Contractor shall include in each Major Subcontract a provision requiring each such Major Subcontractor to comply with and perform for the benefit of Owner all requirements and obligations of Contractor to Owner under this Agreement, to the extent such requirements and obligations are applicable to the performance of the work under the respective Major Subcontract. At a minimum, all Subcontracts shall require the Subcontractors to comply with applicable Laws, Applicable Codes and Standards and Permits, shall provide that Owner has the right of inspection as provided hereunder and require such Subcontractors to (a) be subject to the labor obligations hereunder as well as the safety and security provisions of this Agreement, (b) provide guarantees and warranties with respect to its portion of the Work commensurate with such Major Subcontractor’s work, (c) provide certificates of insurance as set forth herein, (d) grant a license to Owner pursuant to Section 29.2.3, (e) include a termination for convenience provision with terms consistent with the terms set forth herein, and (f) be subject to the confidentiality provisions consistent with the terms set forth herein. Contractor shall use its reasonable efforts to minimize or eliminate cancellation charges or fees in each Subcontract. Additionally, Contractor shall include in each Major Subcontract relating to any Materials or other component of the Facility a requirement that, until the end of the Warranty Period, the Subcontractor shall (i) notify Contractor and Owner in the event Subcontractor intends to discontinue supplying any functional spare parts and (ii) permit Owner to order any quantity of any such parts at the prices prevailing prior to such discontinuance of supply. All Subcontracts must specify that the contractual relationship with the Subcontractor is exclusive to Contractor and that the Subcontractor waives any and all rights to demand any payment directly from Owner.

 

90


 

23.1.3 In addition to the requirements set forth above, Contractor shall include in each Subcontract the following language to make Owner an express third party beneficiary of such Subcontract:

“The parties hereto agree and acknowledge that the services/work/equipment to be provided hereunder by [Subcontractor] will be incorporated into the LNG facility and related facilities being developed by [Owner]. As such, the parties expressly agree that Owner is a third party beneficiary of this [Agreement] entitled, in its own name or in the name of [Contractor], to enforce this [Agreement] against [Subcontractor].”

23.1.4 Contractor shall notify Owner of and coordinate with Owner in connection with the administration of any claim (actual or threatened in writing) arising under any Subcontract or Agent For Contract, and shall request Owner’s approval (such approval not to be unreasonably withheld or delayed) (a) of any external attorney and claims consultant to be appointed by Contractor in connection with such claim and (b) prior to commencing any litigation with respect to such claim. Litigation between Contractor and a Subcontractor or Agent For Contractor shall be jointly managed by Contractor and Owner. Contractor shall not settle any claim arising under a Subcontract or Agent For Contract without Owner’s prior approval.

 

23.2

CONTRACTOR RESPONSIBLE FOR WORK.

Contractor is responsible for each of the various parts of the Work, so that all items thereof conform in all respects to the requirements of this Agreement, regardless of any failure of any Subcontractor to perform, any disagreement between any Subcontractors, or any disagreement between any Subcontractors, on the one hand, and Contractor or Owner. Contractor shall furnish such information relative to its Subcontractors, including copies of unpriced (and with respect to the Reimbursable Work, all priced) Subcontracts as Owner may reasonably request. Without the express written consent of Owner, nothing contained herein or in any Subcontract awarded by Contractor shall create any contractual relationship between Owner and any Subcontractor. Contractor shall require that all Subcontractors release and waive (to the extent permitted by applicable Law) any and all rights against Owner and the Lenders for recovery of payment of any moneys for compensation for the portion of the Work performed by them.

 

23.3

ASSIGNMENT.

23.3.1 Subject to Section 23.3.2, Contractor hereby assigns to Owner (and Owner’s permitted assigns) all its interest in any Subcontracts (or any portion thereof to the extent such Subcontracts also relate to other projects of Contractor) now existing or hereafter entered into by Contractor for performance of any part of the Work, which assignment will be effective upon acceptance by Owner in writing and only as to those Subcontracts which Owner designates in said writing.

 

91


 

23.3.2 Owner shall not have the right to exercise any right to assignment of any Subcontract pursuant to Section 23.3.1 unless and until (a) any obligation by any Subcontractor under any Subcontract extends beyond the expiration of this Agreement, including the Warranty Period, (b) Owner has elected to terminate this Agreement in accordance with the terms hereof or (c) with respect to the Work, Contractor has failed to perform any of its material obligations or correct Defects and Deficiencies under this Agreement to which such Subcontract relates.

23.3.3 Each Subcontract entered into by Contractor with respect to the Work shall contain a provision permitting its assignment to Owner or the Lenders upon Owner’s written request (following the occurrence of any of the events described in Section 23.3.2).

 

23.4

AGENT FOR CONTRACTS WORK.

Owner has agreed to enter into the Agent For Contracts for the performance of the Agent For Contracts Work and to make timely payment when due of amounts owing under the Agent For Contracts directly to the Agent For Contractors. Owner and Contractor acknowledge and agree that Contractor shall have responsibility, and shall be expressly authorized in the Agent For Contracts, to manage and administer the Agent For Contracts and the Agent For Contracts Work thereunder as part of and with the rights and responsibilities of the Work. Except for Owner’s responsibility to make timely payment when due of amounts owing under the Agent For Contracts directly to the Agent For Contractors, Contractor shall be responsible for the performance or nonperformance for any reason of any Agent For Contractor for any other purposes hereunder as to the Work, including with respect to Defects and Deficiencies.

 

24.

LABOR RELATIONS.

24.1 GENERAL MANAGEMENT OF EMPLOYEES.

Contractor shall exercise its management rights in performing the Work, either specifically detailed in, or not expressly limited by, applicable collective bargaining agreement(s). Subject to Section 5.2, such management rights shall be deemed to include the rights to: hire, discharge, promote and transfer employees; to select and remove foremen or other persons at other levels of supervision; to establish and enforce reasonable standards of productivity; to introduce, to the extent feasible, labor-saving equipment and materials; to determine the number of craftsmen necessary to perform a task, job or other work required with respect to the Facility; and to establish, maintain and enforce rules and regulations conducive to efficient and productive operations.

 

24.2

WAGES AND CONDITIONS.

Contractor shall make its own arrangements for the engagement of all staff and labor, local or otherwise, and for their payment, housing, feeding and transport. Contractor shall pay rates of wages, and observe conditions of labor, not materially different than those established for the trade or industry where the work is carried out, and shall comply with all Laws relating to wages, hours, working conditions and other employer/employee-related matters pertaining to its employees. In addition, Contractor shall certify to the reasonable satisfaction of Owner that all social benefit payments related to the wages of all workers employed directly or indirectly by it and its Subcontractors have been timely paid in full.

 

92


 

24.3

VIOLATIONS.

Contractor shall promptly notify Owner of any violations, and the actions to be taken or planned to resolve the violations, of collective bargaining agreements and jurisdictional disputes in connection with the Work including the filing of appropriate processes with any court or administrative agency having jurisdiction to settle, enjoin or award damages resulting from such violations of collective bargaining agreements or jurisdictional disputes.

 

24.4

DISPUTES.

Contractor shall undertake promptly all reasonable efforts to prevent or resolve any strikes or other labor disputes among its employees or the employees of Subcontractors or Agent For Contractors. If a strike or other labor dispute occurs, Contractor shall take all reasonable actions to minimize any resulting disruption of the progress of the Work. Contractor shall advise Owner promptly, in writing, of any actual, anticipated or threatened labor dispute that might affect the performance of the Work by Contractor or by any Subcontractors or Agent For Contractors and will keep Owner informed on a daily basis of the status of the dispute resolution. Notwithstanding the foregoing, the settlement of strikes, walkouts, lockouts or other labor disputes shall be at the sole discretion of the Party having the difficulty. Nothing in this Article 24 shall be deemed to amend the definition of “Force Majeure Event.”

 

24.5

STATUTORY EMPLOYER.

Notwithstanding anything to the contrary contained herein, in all cases where Contractor’s employees (meaning Contractor’s direct, borrowed, special or statutory employees) are covered by the Louisiana Worker’s Compensation Act, La. R.S. 23:1021 et seq., Owner and Contractor agree that Owner shall be and hereby is designated as the statutory employer of Contractor’s direct, borrowed, special and statutory employees, pursuant to La. R.S. 23:1061(A)(3). Owner and Contractor further agree that the Work is an integral part of and essential to Owner’s ability to generate its goods, products and services. This provision is included for the sole purpose of establishing a statutory employer relationship to gain the benefits expressed in La. R.S. 23:1061, and is not intended to create an employer/employee relationship for any other purpose. Nothing contained in this Section 24.5 shall be construed to establish any relationship or status that is inconsistent with Article 37. In the event that Owner is required to pay worker’s compensation benefits to Contractor’s direct, borrowed, special or statutory employees, whether as a statutory employer pursuant to La. R.S. 23:1061 or as a special employer pursuant to La. R.S. 23:1031(C), Owner shall be entitled to reimbursement from Contractor for any such benefit payments. Neither Contractor nor its underwriters shall be entitled to seek contribution from Owner for any worker’s compensation benefits payments made on behalf of any of Contractor’s direct, borrowed, special or statutory employees for purposes of La. R.S. 23:1031(C).

 

24.6

LOCAL LABOR.

Contractor shall use commercially reasonable efforts to attract and retain local labor personnel for the Work and to utilize local Subcontractors whenever possible and cost effective. Contractor agrees to use good faith efforts to award Subcontracts to Subcontractors based in the State of Louisiana and to hire personnel to perform the Work that live in the State of Louisiana.

 

93


 

24.7

COMMUNITY IMPACTS.

Contractor shall use reasonable efforts to assist Owner in creating, assessing and carrying out programs which shall, during all phases of the Work, minimize the impacts upon the host community caused by the construction of the Facility. Such programs shall include sequencing of the Work so as to reasonably minimize the impacts of noise and dust at and around the Job Site.

 

25.

TITLE AND RISK OF LOSS.

 

25.1

TRANSFER OF TITLE.

25.1.1 Contractor warrants and guarantees to Owner good and legal title to the Materials and the Work, and shall deliver and convey ownership of the Materials and the Work free and clear of any and all liens, claims, security interest and other encumbrances, when title thereto passes to Owner. Title to all or any portion of the Materials shall pass to Owner upon the earliest of the following:

 

  (a)

the occurrence of any event by which, under applicable Laws, title passes from Contractor or Subcontractors or Agent For Contractors providing such Materials;

 

  (b)

the date that such Materials are delivered to a shipper for shipment (whether by ship, air, rail, truck or otherwise and whether directly or indirectly) to the Job Site;

 

  (c)

the date that such Materials are delivered to the Job Site; and

 

  (d)

the date of termination of this Agreement, to the extent that Contractor has title.

25.1.2 It is expressly understood and agreed, however, that (a) the passage of title shall not release Contractor from the Contractor’s responsibility to perform fully its obligations hereunder, and (b) in no event shall title to the Owner Furnished Equipment and Materials pass from Owner to Contractor, and Owner shall, at all times, retain title and ownership of the Owner Furnished Equipment and Materials.

 

25.2

RISK OF LOSS.

Notwithstanding passage of title as provided in Section 25.1, Contractor shall bear risk of loss of or damage to the Work and Materials in respect of which Owner has not assumed care, custody and control hereunder until the Facility Substantial Completion Date, but only to the extent (i) of any insurance proceeds actually received by Contractor from claims made under Owner’s Construction and Erection All Risk Insurance Policy or other Owner insurance policies; or (ii) that such loss or damage results from the Gross Negligence or Willful Misconduct of Senior Supervisory Personnel.

 

94


 

25.3

PROTECTION OF OWNER.

For the purpose of protecting Owner’s interest in all Materials and Owner Furnished Equipment and Materials delivered to the Job Site with respect to which title has passed to Owner but which remain in the possession of another party, Contractor shall take or cause to be taken all steps necessary under the Laws of the appropriate jurisdiction(s) to protect Owner’s title and to protect Owner against claims by other parties with respect thereto.

 

26.

INSURANCE.

 

26.1

IN GENERAL.

26.1.1 Contractor and Owner shall procure and maintain the insurance enumerated in this Article 26 as being applicable to it. The provisions of this Article 26 do not modify or change or abrogate any responsibility of Owner or Contractor or any Subcontractor or Agent For Contractor stated elsewhere herein. Neither Owner nor Contractor assumes responsibility for the solvency of any insurer or the failure of any insurer to settle any claim. Contractor shall remain responsible for uninsured losses and deductible amounts under the policies to be provided by Contractor and, with respect to losses arising due to Contractor’s or its Subcontractor’s Gross Negligence or Willful Misconduct of Senior Supervisory Personnel, the policies to be provided by Owner until the Facility Substantial Completion Date, and Owner shall become responsible for such losses and deductibles occurring thereafter.

26.1.2 Contractor shall provide the insurance set forth in Section 26.2 with properly licensed insurance carriers and evidence thereof in a form reasonably satisfactory to Owner and the Lenders’ insurance advisors, which insurance carriers shall be (a) rated A- or higher (with a financial size category of at least FSC VII) by A.M. Best’s Key Rating Guide, (b) rated A or higher by Standard and Poor’s or (c) satisfactory to Owner and the Lenders’ insurance advisor, in their sole discretion. Owner shall provide the insurance set forth in Section 26.3 with properly licensed insurance carriers and evidence thereof and that are reinsured with reinsurers that are (i) rated A-or higher (with a financial size category of at least FSC VII) by A.M. Best’s Key Rating Guide or (ii) rated A or higher by Standard and Poor’s. Subject to Section 26.3.1 the Notice to Proceed and any Limited Notice to Proceed shall not be effective until each of Owner and Contractor has provided to each other such satisfactory evidence of insurance. Each Party shall promptly provide written notification to the other Party if it becomes aware of any material change in, non-renewal or cancellation of insurance coverage that such Party is required to maintain hereunder.

26.1.3 All the liability policies (except workers’ compensation, employer’s liability and professional liability) of insurance shall be endorsed to provide a severability of interests or cross liability clause to the benefit of each additional insured.

26.1.4 All Contractor policies of insurance required under this Article 26 shall provide that such insurance shall not be canceled or not renewed without requiring Contractor to give at least thirty (30) Days’ prior Notice to Owner and the Lenders, except with respect to non-payment of premium, in which case such Notice period shall be ten (10) Days. In addition, all Owner policies of insurance required under this Article 26 shall provide that such insurance shall not be canceled or not renewed without requiring Owner to give at least thirty (30) Days’ prior Notice to Contractor and the Lenders, except with respect to non-payment of premium, in which case such Notice period shall be ten (10) Days.

 

95


 

26.1.5 If any loss or damage to the Work (on or off the Job Site) is sustained, Contractor shall, at the request of Owner, act on behalf of itself and Owner for the purpose of adjusting the amount of the loss with the insurer. Contractor shall (a) replace or repair any such loss or damage and complete the Work in accordance with this Agreement and (b) take such action as may be reasonable and necessary to mitigate the amount of any such loss. Owner and, at the request of Owner, Contractor shall use commercially reasonable efforts for the benefit of the Parties to pursue all claims for loss or damage to property under the policies required to be provided by Owner pursuant to Section 26.3 that exceed the deductible amounts of such policies. As soon as practicable following a loss event, Contractor, Owner and the assigned loss adjuster shall meet to review the loss or damage and determine the course of action required to remedy the loss or damage. To the extent possible, Contractor and Owner shall determine with the loss adjuster the extent of loss or damage and the level of insurance coverage applicable to such loss or damage. Contractor shall cooperate with and provide the loss adjuster information relevant to the loss or damage, the schedule impact estimates of remediation, and any other reasonable information sought by insurers concerning the loss event. Contractor shall keep Owner reasonably informed of the status of claims negotiations with the insurer for which Contractor is, at the request of Owner, responsible under the Construction and Erection All Risk insurance required to be obtained by Owner pursuant to Section 26.3.1. For the avoidance of doubt, Owner shall remain the sole authority on any decisions related to claims handling, coordination and acceptance of payment on all Owner-procured insurance policies. Advance payments under the applicable insurance policy may be requested of insurers in order to facilitate cash flow and in no event shall Contractor be relieved of its obligation to repair and replace the loss or damage if such advance is not made.

26.1.6 Subject to the requirements and limitations set forth in Sections 26.1.5, (a) Contractor shall include with each Request for Payment any amounts payable by Owner pursuant to this Section 26.1.6 and (b) provided that Contractor comply with all requirements for payment set forth herein, Owner shall pay such amounts in accordance with the terms of this Agreement.

 

26.2

POLICIES TO BE OBTAINED BY CONTRACTOR.

26.2.1 Except for the Construction and Erection All Risk insurance required to be provided by Owner pursuant to Section 26.3.1(a) and Commercial General Liability insurance required to be provided by Owner pursuant to Section 26.3.1(b), Contractor shall obtain and maintain in full force and effect, and shall require, as applicable, Subcontractors to procure and maintain in full force and effect, the following insurance:

(a) General liability insurance written on ISO occurrence form CG 00 01 04/13 covering all activities of Contractor other than the Work at the Job Site, and shall include Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer as additional insureds on a primary and noncontributory basis to the extent of the indemnity obligations assumed by Contractor under this Agreement. Such insurance shall be written in an amount of [***] per occurrence and [***] annual aggregate including a [***]

 

96


 

aggregate limit for products and completed operations. Such insurance shall be endorsed to include coverage for products and completed operations for ten (10) years after the Facility Substantial Completion Date or the statute of repose, whichever is less. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed by Contractor under this Agreement;

(b) Workers Compensation, and if applicable, United Longshore and Harbor Workers Compensation Act insurance and Jones Act coverage, or similar insurance in the form prescribed by relevant laws and insuring against work related losses and claims arising in connection with the performance of the Work by Contractor. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed under this Agreement by Contractor;

(c) Employer’s Liability with limits available under a primary or excess policy equal to the equivalent of [***] per accident/occurrence or such higher limit as may be required by Laws. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed under this Agreement by Contractor;

(d) Automobile Liability Insurance applicable to all owned, non-owned, hired and leased automotive equipment used in the performance of the Work, including contractual liability, with limits of [***] per accident/occurrence combined single limit including Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer as additional insureds on a primary and noncontributory basis to the extent of the indemnity obligations assumed under this Agreement by Contractor. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed under this Agreement by Contractor;

(e) Umbrella/Excess Liability Insurance providing coverage over the underlying insurance required in Sections 26.2.1(a), 26.2.1(c), and 26.2.1(d) with limits of [***] per occurrence and in the annual aggregate. Such insurance shall include Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer as additional insureds on a primary and noncontributory basis, and include a waiver of subrogation in favor of such additional insureds to the extent of the indemnity obligations assumed by Contractor under this Agreement;

 

97


 

(f) Contractor shall maintain or require to be maintained Professional Liability Insurance, on account of any errors or omissions of Contractor and Subcontractors involved in Work contracted hereunder with liability limits of insurance of [***] per claim and [***] in the aggregate during construction and for a five (5) year period after Final Completion;

(g) Contractor shall either (i) maintain or require to be maintained project specific Pollution Liability Insurance, for any event caused or exacerbated by actions or inactions of Contractor and Subcontractors involved in Work contracted hereunder with liability limits of insurance of at least [***] per occurrence and [***] in the annual aggregate during construction and include Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer as additional insureds on a primary and non-contributory basis, and include a waiver of subrogation in favor of such additional insureds, or (ii) provide Owner and the Lenders with such security as is deemed sufficient by such parties to cover any such errors and omissions; and

(h) For all vessels owned, operated, chartered, or brokered by or for Contractor or any of the Subcontractors in connection with the Work, Contractor shall carry or require the owner or operator of such vessels to carry watercraft insurance, as follows: (i) Hull Insurance for full fair value; (ii) Protection and Indemnity Insurance under Form SP-23 (Revised 1/56), or most recent version, to cover liabilities arising out of the ownership, operation and use of any vessel with liability limits of insurance of [***] per occurrence, including (y) pollution and environmental liability insurance upon such vessels for damages, cleanup and restoration costs, in amount no less than those limits required by applicable Law and coverage for crew and personnel on such vessels, with no exclusion for activities arising from the use of remote operated vehicles and submarines and diving operations (if these operations are to be performed under this Agreement), and (z) including collision and tower’s liability, cargo legal liability (to the extent applicable), and coverage for liabilities for the removal of wreck or debris as compulsory under statute or as requested by applicable Government Authorities. Insurers shall waive any right to limit liability to the value of the vessel, but only with respect to Owner indemnified parties, whichever is applicable, and the phrase “as owner of vessel named herein” and all similar phrases purporting to limit the insurer’s liability to that of an owner shall be deleted. The coverage in clause (y) regarding pollution and environmental liability insurance for damages, cleanup and restoration costs (in amount no less than those limits required by applicable Law) may be provided under a marine pollution liability policy; provided that such policy provides the same coverage and limits that would be provided under the protection and indemnity insurance. Should the Work necessitate the use of remotely operated vehicles or dredging, this protection and indemnity insurance shall include a specialist operation endorsement; and (iii) Charterer’s Legal Liability Insurance to cover liabilities arising out of operation and use of any time or voyage chartered vessel including coverage for contractual liability for those liabilities assumed by Contractor herein with liability limits of insurance of [***] per occurrence. The insurance listed in clauses (y) and (z) above shall provide that seaworthiness of vessels used to perform Work hereunder is accepted by insurers (or that insurers shall waive in favor of Owner indemnified parties, the vessel owner’s and/or Contractor’s warranty of seaworthiness).

 

98


 

26.2.2 Each policy described under this Section 26.2 shall contain terms and conditions reasonably acceptable to Owner and the Lenders and shall be issued by insurers reasonably acceptable to Owner, and Contractor shall forward to Owner certificates evidencing the coverage is in effect.

26.2.3 Contractor shall be responsible for additional costs associated with modifying any inadequate coverage, terms and conditions to meet the requirements of this Section 26.2. Contractor shall comply with all the conditions and requirements provided for in its insurance policies and to the extent Contractor has been notified in writing of such conditions and requirements the policies required to be maintained by Owner pursuant to Section 26.3. Contractor shall make no material adverse alteration to the terms of any insurance required herein without the prior written approval of Owner and the Independent Engineer. If an insurer makes (or purports to make) any such alteration, Contractor shall notify Owner immediately.

26.2.4 Contractor shall require all insurers under Contractor’s insurance policies to provide Owner and such other interested Persons as may be designated by Owner with certificates of insurance, in form and substance reasonably acceptable to Owner, evidencing and describing the insurance policies and endorsements maintained hereunder prior to commencement of the Work, or upon issuance of such policies, if earlier, and prior to each issuance anniversary date throughout the term of this Agreement. The certificates of insurance shall evidence and describe the insurance policies and endorsements. Notwithstanding anything to the contrary contained herein, evidence of such coverage shall be provided to Owner as a condition precedent to the commencement of the Work.

26.2.5 In respect of all of the Contractor’s insurance policies, Contractor shall, on or before the Notice to Proceed Date and as may be requested by Owner from time to time, produce the Contractor’s certificates of insurance, and required endorsements. If policies have been secured on a project specific basis, Contractor shall provide the actual policy upon written request by Owner.

26.2.6 Before permitting any of its Subcontractors to perform any Work at the Job Site, Contractor shall obtain a certificate of insurance from each such Subcontractor evidencing that such Subcontractor has obtained the insurance required of Subcontractors by Contractor, such insurance at a minimum to include Workers Compensation, and if applicable, United Longshore and Harbor Workers Compensation Act insurance and Jones Act coverage, general liability, employer’s liability and umbrella/excess liability insurance and, with respect to Subcontractors that charter a vessel for the purpose of their work, the insurance described in Section 26.2.1(h). Policies provided by Subcontractors shall be in amounts and upon conditions as are customarily and normally provided for work similar to the Work. Contractor shall use reasonable efforts to cause all Major Subcontractors to include in their respective insurance policies a waiver of any right of subrogation of the insurers thereunder against Owner, the Lenders, the Independent Engineer and Contractor, and any right of the insurers to set off or counterclaim, offset or any other deduction, whether by attachment or otherwise, in respect of any liability of any such Person insured under such policy.

26.2.7 If Contractor shall fail to obtain and keep in force insurance required pursuant to this Section 26.2, Owner may, without limiting any other remedy it may have, obtain and keep in force any such insurance and pay such premium or premiums as may be necessary for that purpose and recover from Contractor whether by way of deduction, offset or otherwise the cost of obtaining and maintaining such insurance.

 

99


 

26.2.8 Except as directed by Owner, Contractor shall be responsible for managing and administering all of Contractor’s insurance policies, including the payment of all deductibles pursuant to Section 26.1.1 and self-insured retention amounts, the filing of all claims and the taking of all necessary and proper steps to collect any proceeds on behalf of the relevant insured Person. Contractor shall at all times keep Owner informed of the filing and progress of any claim arising out of or relating to the Work. If Contractor shall fail to perform these responsibilities, upon reasonable written notice Owner may take such action as it determines appropriate under the circumstances. In the event Contractor collects proceeds on behalf of other Persons, it shall ensure that these are paid directly from the insurers to the relevant Person and, in the event that it receives any such proceeds, it shall, unless otherwise directed by Owner, pay such proceed to such Party forthwith and prior thereto, hold the same in trust for the recipient.

26.2.9 All equipment, tools, supplies and materials belonging to Contractor or any Subcontractor and used by Contractor or such Subcontractor for the performance of the Work and not to be incorporated into or to be left at the Facility shall be brought to and kept at the Job Site at the cost and risk of Contractor or such Subcontractor, and Owner shall not be liable for loss or damage thereto and any insurance policies carried by Contractor or Subcontractors shall waive the insurer’s right to subrogation against Owner, the Lenders and the Independent Engineer, and their respective assignees, subsidiaries, Affiliates and employees. Contractor shall obtain, or shall cause Subcontractors to obtain, adequate insurance to cover any construction tools and equipment leased from Third Parties.

 

26.3

POLICIES TO BE OBTAINED BY OWNER.

26.3.1 From and after the earlier of the Notice to Proceed Date and such other date as the Parties may mutually agree upon in writing (whether earlier or later) through Final Completion, Owner shall obtain and maintain in full force and effect at its cost, the following insurance with respect to the procurement, construction, erection, Pre-Commissioning, Commissioning, testing and pre-completion operation of the Materials, the Work at the Job Site and the Facility; provided that Owner shall not be obligated to obtain Construction and Erection All Risk insurance before the date upon which Contractor or any Subcontractor will begin Work at, or deliver Materials to, the Job Site:

(a) Construction and Erection All Risk insurance (excluding Contractor’s and Subcontractors’ equipment and property not intended to be installed into the Facility). Such insurance policy shall be written on a replacement cost basis and be in the joint names of Owner and the Lenders as named insureds and Contractor and Subcontractors as additional insureds with a waiver of the insurer’s rights of subrogation in favor of all such named insureds and additional insureds. The deductible under such insurance shall be consistent with the terms reasonably and commercially available in the insurance marketplace considering the equipment and maturity of its design and location. The policy shall also provide, in amounts reasonably acceptable to the Lenders, (i) coverage for removal of debris, (ii) transit coverage with worldwide coverage territory including the continental boundaries of the United States of America and intracoastal waterways

 

100


 

adjacent thereto, not including air and ocean marine coverage, (iii) off-site storage coverage, (iv) pollution clean-up and removal (with per occurrence and policy aggregate sublimits), (v) professional fees, (vi) operational and performance testing, (vii) earth movement, flood, named windstorm, expediting expense (with per occurrence and policy aggregate sublimits), (viii) minimization of loss expense, (ix) design defect clause no more restrictive than LEG 2/96, (x) 50/50 hidden damage clause, (xi) advance payment clause and (xii) fire department charges clause. The deductible under such insurance shall be for Owner’s account. Owner may, in its sole discretion, carry and maintain Delay in Commissioning or Start -up insurance covering at least Owner’s debt service payments (principal and interest), and as the Lenders may require, continuous fixed expenses and additional expenses incurred as a result of loss or damage covered under the insurance provided pursuant to Sections 26.3.1(a) and 26.3.1(c) . Any recovery under the Delay in Commissioning or Start-up coverage will accrue to the benefit of Owner. If an event or events occur that may be covered by the Delay in Commissioning or Start-up insurance, it shall be Owner’s sole option to decide whether to file a claim under such Delay in Commissioning or Start-up insurance.

(b) Owner Controlled Insurance Program for Commercial General Liability insurance with a limit of at least [***] per occurrence and in the aggregate for bodily injury and property damage at the Job Site. Such coverage shall name Owner, the Lenders, Contractor and Subcontractor as insureds with a waiver of subrogation in favor of any insured and shall include a severability of interest and cross liability provision. Coverage may be arranged in combination of primary and excess coverage. The deductible shall be for Owner’s account. Owner’s procurement and provision of this insurance shall in no way relieve Contractor or any Subcontractor of any responsibility or liability under this Agreement, any applicable law, statute, regulation or order.

(c) Subject to prevailing terms in the insurance marketplace, air and ocean cargo coverage for all Materials shipped to the Job Site (other than locally procured Materials) and insuring the interest of Owner, the Lenders, Contractor and Subcontractors written on a warehouse to final destination basis from customary “all risk” air and marine perils while in transit. Such policy shall be written on replacement cost basis or in such other amounts acceptable to Owner, the Lenders and Contractor, and shall be subject to a per conveyance limit equivalent to the maximum value of the shipment. The deductibles under such insurance shall be for Owner’s account. Contractor shall provide Owner with schedules and Notices of air and marine shipments pursuant to Section 3.8.18. Owner shall be responsible for any required load survey costs incurred in connection with any shipment of Materials or equipment for Work performed under this Agreement.

(d) Upon the LNG Production System Substantial Completion of each LNG Production System, Owner shall have in place a Commercial Property Policy for such LNG Production System and corresponding LNG Production System Handover Package from the time care, custody and control of such LNG Production System Handover Package transfers from Contractor to Owner in accordance with Section 18.1.3. Such policy shall contain a waiver of subrogation in favor of Contractor and its Subcontractors.

26.3.2 Owner shall also provide Contractor with satisfactory evidence of the existence of insurance policies obtained by Owner prior to an effective Notice to Proceed Date and copies of the policies of insurance obtained by Owner not later than thirty (30) days following the Notice to Proceed Date.

 

101


 

26.3.3 Insurance required to be maintained by Owner hereunder shall be subject to standard sublimits and exclusions available in the insurance marketplace.

26.3.4 All insurance referred to in this or any other Section of this Agreement shall be subject to review and acceptance by the Lenders, and Contractor shall assist as necessary in arranging and maintaining all such insurance and shall not do or omit to do anything that may cause such policy to be invalidated or a valid claim to be repudiated.

26.3.5 Each of Owner and Contractor shall also purchase insurance that may be statutorily required from time to time and/or enroll employees in such state schemes as may be so required at each Party’s own expense during the term of this Agreement.

26.3.6 Contractor shall cooperate with Owner and its insurers to provide any information requested by the insurers necessary to obtain such extension to the insurance policies.

 

27.

CONFIDENTIAL TREATMENT OF PROPRIETARY INFORMATION; RELIANCE ON INFORMATION.

 

27.1

CONFIDENTIAL TREATMENT.

27.1.1 Contractor covenants and warrants (on behalf of its Representatives) that it shall not (without in each instance obtaining Owner’s prior written consent) disclose, make commercial or other use of, or give or sell to any Person any non-public information regarding Owner, its Affiliates or the Facility (including commercially sensitive information related to the transactions contemplated hereby) (“Confidential Information”); provided, however, that Contractor may disclose such Confidential Information (but only to the extent necessary) (a) to its Representatives, Subcontractors and suppliers who have a need to know such Confidential Information, (b) to its counsel, (c) to any Government Authority to the extent required by Law to be disclosed, (d) under seal in connection with any arbitration, mediation or litigation or (e) to the Lenders or the Independent Engineer in connection with the Financing or insurance underwriters in connection with the Work; provided, further, that any Confidential Information disclosed pursuant to clauses (a), (b), (d) and (e) shall not be disclosed unless (i) the recipient is informed as to the confidential nature of such information, (ii) the recipient agrees to a separate confidentiality agreement with terms and conditions as least as restrictive as this Section 27.1.1 as a condition to the receipt of such Confidential Information and (iii) the disclosing Party remains liable for any breach of this Section 27.1.1 if the breach is caused by the disclosing party or its officers or employees; provided, further, that prior to any disclosure of Confidential Information pursuant to clause (c), Contractor shall give reasonable notice to Owner of the information required to be disclosed and, to the extent reasonably capable under applicable Law and the circumstances surrounding the disclosure, shall provide Owner with an opportunity to take appropriate steps Owner believes are necessary to protect the confidentiality and/or proprietary nature of its Confidential Information. Contractor shall not, nor shall it permit any of its subsidiaries or Affiliates to, issue or cause the publication of any press release or other public statements, announcements or disclosure with respect to this Agreement or the transactions contemplated hereby, or otherwise use Owner’s trademarks, service

 

102


 

marks, trade names, logos, domain names, or other indicia of source, association, or sponsorship, without the written consent of Owner. The duration of the obligations stated in this Section 27.1 shall be (x) for Confidential Information that is identified by Owner to be a trade secret, for so long as such Confidential Information remains confidential, and (y) for all other Confidential Information, for a period of [***] years after the expiration or termination of this Agreement. Information shall not be deemed to be “Confidential Information” where: (A) it is or becomes public information or otherwise generally available to the public through no act of or failure to act by Contractor; (B) it was, prior to the Effective Date, already in the possession of Contractor and was not received by Contractor directly or indirectly from Owner and is not subject to a confidentiality agreement; (C) it is rightfully received by Contractor from a third party who is not prohibited from disclosing it to Contractor and is not breaching any agreement by disclosing it to Contractor; or (D) was independently developed by the Contractor without the use of any Confidential Information of Owner. Specific information shall not be deemed to be within the exceptions of the previous sentence merely because it is embraced by more general information within such exceptions, nor shall a combination of features be deemed to be within such exceptions merely because the individual features are within such exceptions. Contractor acknowledges that in the event of a breach of any of the terms contained in this Article 27, Owner may suffer irreparable harm for which remedies at law, including damages, would be inadequate, and that Owner shall be entitled to seek equitable relief therefor by injunction, in addition to any and all rights and remedies available to it at law and in equity, without the requirement of posting a bond.

27.1.2 Without limiting Section 27.1.3, Owner covenants and warrants (on behalf of its Representatives and the Independent Engineer ) that it shall not (without in each instance obtaining Contractor’s prior written consent) disclose, make commercial or give or sell to any Person any non-public information regarding the Contractor’s reimbursable or unit rates, the liability and liquidated damages caps set forth in this Agreement, Contractor Intellectual Property, or other commercial information of Contractor unrelated to the Facility, the Work, this Agreement and not required to be provided or licensed to Owner under Article 29 (collectively, “Contractor Confidential Information”); provided, however, that Owner may disclose the Contractor Confidential Information listed in (i) above (but only to the extent necessary) to the parties listed in Section 27.1.1 (a) through (e) above, applied on a mutatis mutandis basis, and Owner’s existing or potential LNG offtakers and buyers, and so long as the recipient agrees to maintain the confidentiality of Contractor Confidential Information on terms and conditions as least as restrictive as those set forth herein; and provided, further, that, except as necessary for Owner to invoice any Owner Contractor for corrective or remedial work performed by Contractor, Owner shall not directly or indirectly provide the Contractor Confidential Information to any engineering, construction and procurement contractor (including UOP, BH and CB&I) that provides engineering, construction and procurement services for chemical or LNG facilities as a substantial part of its business without the prior written consent of the Contractor. Section 27.1.2 shall apply on a mutatis mutandis basis to Contractor Confidential Information. Owner acknowledges that in the event of a breach of any of the terms contained in this Article 27, Contractor may suffer irreparable harm for which remedies at law, including damages, would be inadequate, and that Contractor shall be entitled to seek equitable relief therefor by injunction, in addition to any and all rights and remedies available to it at law and in equity, without the requirement of posting a bond. Information shall not be deemed to be “Contractor Confidential Information” where: (A) it is or becomes public information or otherwise generally available to the public through no act of or failure to act by Owner; (B) it was, prior to the Effective Date, already in the possession of

 

103


 

Owner and was not received by Owner directly or indirectly from Contractor and is not subject to a confidentiality agreement; (C) it is rightfully received by Owner from a third party who is not prohibited from disclosing it to Owner and is not breaching any agreement by disclosing it to Owner; or (D) was independently developed by Owner without the use of any Contractor Confidential Information. Specific information shall not be deemed to be within the exceptions of the previous sentence merely because it is embraced by more general information within such exceptions, nor shall a combination of features be deemed to be within such exceptions merely because the individual features are within such exceptions.

27.1.3 All right and title to, and interest in, the Confidential Information shall remain with Owner. All Confidential Information obtained, developed or created by or for Contractor exclusively for the Facility, including copies thereof, is and shall be the sole and exclusive property of Owner (except Contractor Intellectual Property contained therein, which will be governed by Section 0), whether delivered to Owner or not, and Contractor agrees to assign and hereby assigns any and all right, title, and interest therein it may have to Owner, in each case subject to Section 29.1. No right or license is granted to Contractor or any third party respecting the use of Confidential Information by virtue of this Agreement, except to the limited extent required for the Contractor’s performance of its obligations hereunder. Contractor shall cease all use of and deliver to Owner or destroy all Confidential Information, including all copies thereof, upon Owner’s request, provided Contractor may retain a copy of the Confidential Information to comply with applicable Law, and to the extent any routine computer back -up procedures create copies in the associated back-up or archival computer storage system. Such copies retained shall remain subject to the provisions of this Agreement.

 

27.2

RELIANCE ON INFORMATION.

Subject to Article 29, Owner shall have unrestricted use of Drawings and Specifications provided to Owner pursuant to this Agreement. Owner shall defend, indemnify, and hold the Contractor Indemnitees harmless from and against any use by Owner, its Affiliates, other contractors, representatives, or agents of the Drawings and Specifications for any purpose other than for the Facility or the Phase 1 Facility; provided, Owner shall not be required to indemnify the Contractor Indemnitees under this Section 27.2 and the Phase 1 Agreement for the same harm, (without, for the avoidance of doubt, limiting Owner’s respective indemnity obligations under this Agreement or the Phase 1 Agreement).

 

28.

REPRESENTATIONS AND WARRANTIES.

 

28.1

OWNER REPRESENTATIONS AND WARRANTIES. Owner represents and warrants that as of the Effective Date:

28.1.1 Owner is a limited liability company duly organized and validly existing in good standing under the laws of the State of Delaware and has all necessary power and authority to enter into and perform its obligations under this Agreement;

28.1.2 Each of the execution, delivery and performance by Owner of this Agreement has been duly authorized by all necessary action on the part of Owner and does not contravene or constitute a default under any provision of applicable Law, the constituting documents or the certificate of formation of Owner or of any other agreement, judgment, injunction, order, decree or other instrument binding upon Owner;

 

104


 

28.1.3 Owner has duly executed and delivered this Agreement and, assuming the due authorization, execution and delivery thereof by Contractor, this Agreement constitutes (or when so executed and delivered will constitute) a valid and binding obligation of Owner enforceable against Owner in accordance with its terms, except that (a) such enforceability may be limited by applicable bankruptcy, insolvency, reorganization, liquidation, moratorium or similar laws affecting creditors’ rights generally and (b) the application of general equitable principles may limit the availability of certain remedies; and

28.1.4 There is no pending action, suit, proceeding, inquiry or investigation against it, at law or in equity or before or by any Government Authority, of which it has received notice, or which it has knowledge is threatened which would materially and adversely affect its ability to perform its obligations under this Agreement. It is not in violation of any Law which, individually or in the aggregate, would affect its performance of any obligations under this Agreement.

 

28.2

CONTRACTOR REPRESENTATIONS AND WARRANTIES.

Contractor represents and warrants that as of the Effective Date:

28.2.1 It is a limited liability company duly organized and validly existing in good standing under the laws of the State of Texas, is wholly-owned, collectively, by the JV Members, and has all necessary power and authority to carry on its business as presently conducted, to own or hold under lease its properties and to enter into and perform its obligations under this Agreement;

28.2.2 Each of the execution, delivery and performance by it of this Agreement has been duly authorized by all necessary action on its part, does not require any approval, except as has been heretofore obtained, of its board of directors or shareholders or any consent of or approval from any trustee, lessor or holder of any indebtedness or other obligation of it, except for such as have been duly obtained, and does not contravene or constitute a default under any provision of applicable Law, its constituting documents (including the JV Agreement) or by-laws or of any agreement, judgment, injunction, order, decree or other instrument binding upon it, or subject the Facility or any component part thereof or the Job Site or any portion thereof to any lien other than as contemplated or permitted by this Agreement; and it is in compliance with all applicable Laws (a) which govern its ability to perform its obligations under this Agreement or (b) the noncompliance with which would have a material adverse effect on it;

28.2.3 Neither the execution and delivery by it of this Agreement, nor the consummation by it of any of the transactions contemplated hereby, requires the consent or approval of, the giving of notice to, the registration with, the recording or filing of any document with, or the taking of any other action in respect of any Government Authority, except such as are not yet required, and it has no reason to believe that the same will not be readily obtainable in the ordinary course of business upon due application therefor, or which have been duly obtained and are in full force and effect;

 

105


 

28.2.4 It has duly executed and delivered this Agreement, and, assuming the due authorization, execution and delivery thereof by Owner, this Agreement constitutes (or when so executed and delivered will constitute) its valid and binding obligation, enforceable against it in accordance with its terms, except that (a) such enforceability may be limited by applicable bankruptcy, insolvency, reorganization, liquidation, moratorium or similar laws affecting creditors’ rights generally and (b) the application of general equitable principles may limit the availability of certain remedies;

28.2.5 Contractor has substantial experience and all the required skills and capacity necessary for the engineering, procurement and fabrication of Materials used in LNG export and liquefaction facilities comparable to the Facility, and is fully qualified to engineer, procure and construct the Work and otherwise perform the Work in accordance with this Agreement;

28.2.6 It understands that as background information and as an accommodation to it, prior to the Effective Date Owner may provide or may have provided it with copies of certain studies, reports or other information. It further acknowledges and agrees that (a) Owner makes no representations or warranties with respect to the accuracy of such documents or the information or opinions therein contained or expressed unless expressly stated herein (including any Exhibit hereto), (b) Owner shall not be liable to it in contract, tort or otherwise as a result of the use of such information by it, except as expressly provided herein and (c) except for the Relied Upon Information, it shall not rely upon such information without satisfying itself as to its accuracy and completeness;

28.2.7 It (a) has examined this Agreement, including all Exhibits attached hereto, thoroughly and become familiar with all its terms and provisions and to the best of its knowledge, it has reviewed all other documents and information necessary and available to it in order to ascertain the nature, location and scope of the Work, the character and accessibility of the Job Site and surrounding area, the existence of obstacles at the Job Site and surrounding area to the performance of the Work, the availability of facilities and utilities, and the location and character of any existing or adjacent work or structures, and based on such examination and review has no reason to believe that it will be unable to complete the Work in accordance with this Agreement and (b) expressly waives any claims for additional compensation, reimbursement, damages, liabilities or time extension in connection with such conditions, except as otherwise provided herein including Sections 3.3 and 12.4;

28.2.8 There is no pending action, suit, proceeding, inquiry or investigation against it, at law or in equity or before or by any Government Authority, of which it has received notice, or which it has knowledge is threatened which would materially and adversely affect its ability to perform its obligations under this Agreement. It is not in violation of any Law which, individually or in the aggregate, would affect its performance of any obligations under this Agreement;

28.2.9 The terms and conditions of the JV Agreement are substantially consistent with the terms and conditions described in that certain Memorandum of Understanding between the JV Members that was disclosed to Owner prior to the Effective Date and do not materially impair the ability of the Contractor to perform any of its obligations under this Agreement; and

 

106


 

28.2.10 None of the Inventions, Materials or the design, engineering and other Work or services rendered by it hereunder, nor the use or ownership thereof by Owner, infringes, as of the Effective Date or prior to Final Completion violates or constitutes a misappropriation of any third party Intellectual Property rights (including any trade secrets, proprietary rights, patents, or copyrights) or trademark, and Contractor further has all requisite rights to grant Owner such rights specified in Article 29.

 

29.

INTELLECTUAL PROPERTY AND LICENSES.

 

29.1

OWNERSHIP.

Contractor shall disclose promptly in writing to Owner all inventions, discoveries, developments and other Intellectual Property which it or its employees or agents (a) may make, create, develop, invent, conceive or first reduce to practice which are based on or derived from Confidential Information or other proprietary information received from Owner or (b) made, created, developed, invented, conceived or first reduced to practice hereunder for the purposes of the Work (but excluding Contractor Intellectual Property) ((a) and (b) collectively, “Inventions”). All right, title and interest (including all Intellectual Property rights other than Contractor Intellectual Property) in and to all such Inventions, as well as any Deliverables (including all Intellectual Property rights therein other than Contractor Intellectual Property) provided hereunder, shall be the sole and exclusive property of Owner, and Contractor agrees to assign and hereby assigns all such right, title, and interest in and to all such Inventions and Deliverables (including all Intellectual Property rights therein other than to Contractor Intellectual Property) to Owner. Contractor retains all right, title and interest to all Contractor Intellectual Property. Nothing in this Agreement grants to Contractor any right under or to Owner’s Intellectual Property.

 

29.2

LICENSES.

29.2.1 From the receipt of the first payment on or following the Notice to Proceed Date, Contractor hereby grants to Owner and its Affiliates (and shall procure for Owner from any Subcontractors) a perpetual, irrevocable (so long as Owner has not been finally adjudged by court or arbitral tribunal to be in material breach of its payment obligations hereunder), royalty-free, transferable (limited to its Affiliates, any Lender exercising any step-in rights or any owner of the Facility), worldwide, nonexclusive license in, to, and under the Contractor Intellectual Property to copy, modify, reproduce, distribute, practice, and otherwise utilize the same to the extent reasonably necessary for the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, reconstruction, alteration or modification of the Facility (including any portion, subsystem, unit or component thereof), but not including the right to grant sublicenses to third parties except in connection with and as necessary for the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem, unit or component thereof) or to accomplish an above-permitted transfer.

29.2.2 Contractor agrees to execute or have executed all documents, and to perform or have performed all lawful acts that Owner may deem reasonably desirable or necessary to perfect its (or its designee’s) ownership of or license(s) to which it is entitled pursuant to this Article 29.

 

107


 

29.2.3 Contractor shall, prior to directing any Subcontractors or Agent For Contractor to perform any part of the Work, obtain a valid written assignment and license from each such Subcontractor or Agent For Contractor covering the same items and on identical (or if identical terms cannot be obtained, despite Contractor’s commercial reasonably efforts to do so and so long as prior written notice is provided to Owner, equivalent) terms as those that obligate Contractor to the Owner as expressed in this Article 29.

 

29.3

DATA.

Subject to the retention by Contractor of all Contractor Intellectual Property, all Drawings and Specifications furnished or required to be furnished by Contractor to Owner in performing the Work (including all Intellectual Property rights therein) are and shall be the sole and exclusive property of Owner, and Contractor agrees to assign and hereby assigns all such right, title and interest in and to all such Drawings and Specifications (including all Intellectual Property rights therein, but excluding Contractor Intellectual Property) to Owner. From the Effective Date, Contractor grants to Owner, without limitation of Section 29.2.1, a perpetual, irrevocable (so long as Owner has not been finally adjudged by court or arbitral tribunal to be in material breach of its payment obligations hereunder), worldwide, nonexclusive, nontransferable (except to Owner’s Affiliates, any Lender exercising step-in rights or any owner of the Facility), royalty-free right to use all Intellectual Property included in the Drawings and Specifications (including technical information and software), that is not owned by Owner, all for the purpose of the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (including any portion, subsystem, unit or component thereof), but not including the right to grant sublicense to third parties except in connection with and as necessary for the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem, unit or component thereof) or to accomplish an above-permitted transfer.

 

30.

INDEMNIFICATION.

 

30.1

CONTRACTOR INDEMNITY.

30.1.1 Contractor shall defend, indemnify, and hold the Owner Indemnitees harmless from and against any and all Losses incurred by any such Owner Indemnitees to the extent arising from or based on any Intellectual Property Claim. If any use, operation, or enjoyment of the Facility or any part thereof is the subject of an Intellectual Property Claim, then, in addition, Contractor shall promptly, but in no event later than thirty (30) days from the date of notice from Owner, commence action to remove such impediment, and thereafter shall diligently pursue removal of such impediment, (at Contractor’s option) by: (a) procuring for Owner, or reimbursing Owner for procuring, the right to continue using the subject of the Intellectual Property Claim; (b) modifying the subject of the Intellectual Property Claim to avoid the alleged infringement, disclosure, use, misappropriation or other violation, while maintaining substantially the same performance, quality and expected life satisfying the requirements of this Agreement, to the reasonable satisfaction of Owner; or (c) replacing the subject of the Intellectual Property Claim with service, Materials, Inventions, or other Work or Contractor Intellectual Property, as applicable, of comparable functionality and quality and satisfying the requirements of this Agreement, to the reasonable

 

108


 

satisfaction of Owner, that avoids the alleged infringement, disclosure, use, misappropriation or other violation; provided that in no case shall Contractor take any action which materially and adversely affects Owner’s continued completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem or component thereof) without the prior written consent of Owner; and provided further, that in no event shall Contractor have such indemnity obligations or obligation to remove such impediment for any Intellectual Property Claim arising from or in connection with (i) the Owner Furnished Equipment and Materials or any written instruction, written information, designs, specifications, or other materials provided by Owner to Contractor, (ii) any action or omission of any Owner Contractor, or (iii) any modification of the Work directed by Owner or that was not authorized by Contractor. For the avoidance of doubt, Owner’s acceptance of the Materials, Deliverables, Inventions, and other equipment or any other component of the Work shall not be construed to relieve Contractor of any obligation hereunder. Owner shall, and shall cause other Owner Indemnitees to, agree to reasonably cooperate and assist Contractor in the defense of any Intellectual Property Claims, at Contractor’s cost. Any Owner Indemnitee that seeks to settle any Intellectual Property Claim shall seek the prior approval of Contractor, which approval shall not be unreasonably withheld, conditioned, or delayed, in respect of such settlement. Contractor shall not settle any Intellectual Property Claim that includes any non-monetary obligations without the prior approval of Owner, which approval shall not be unreasonably withheld, conditioned, or delayed, in respect of such settlement.

30.1.2 In addition to its indemnification, defense and hold harmless obligations contained elsewhere herein, to the fullest extent permitted by Law, Contractor assumes liability for, and agrees to indemnify, protect, save and hold harmless and defend each of the Owner Indemnitees from and against any and all Losses (including any strict liability, all fines and penalties as well as reasonable attorneys’ fees, consultant fees, experts’ fees and litigation expenses) of whatsoever kind and nature that may be imposed on, suffered or incurred by or asserted against any Owner Indemnitee in any way relating to or directly or indirectly arising out of (a) the presence, Release or threatened Release of any Hazardous Substance used, generated or handled by or brought to the Job Site or disposed by or at the direction of Contractor or any Subcontractor or Agent For Contractor (but in all cases, excluding (i) Pre-Existing Hazardous Substances (except to the extent of Contractor’s or its Subcontractors’ or such Agent For Contractor’s noncompliance with Section 3.8.46; or (ii) Gross Negligence or Willful Misconduct of (1) Senior Supervisory Personnel or (2) comparable personnel of a Subcontractor or Agent For Contractor (limited to the extent of any recovery by Contractor from such Subcontractor or Agent For Contractor) in the handling, storage or transportation of any Pre-Existing Hazardous Substance after discovery of such Pre-Existing Hazardous Substance by Contractor or a Subcontractor or Agent For Contractor); or (iii) claims arising out of Owner’s Gross Negligence or Willful Misconduct in the handling, storage or transportation of Hazardous Substances brought to the Site by Contractor), (b) bodily injuries (including wrongful death) or property damage of Third Parties (with respect to bodily injuries, “Third Parties” shall include Owner’s employees), to the extent caused by the negligent acts or omissions of Contractor, any worker or any Subcontractor or anyone for whose acts they may be liable arising in connection with the performance of the Work, (c) fines and penalties arising out of the violation by Contractor or any Subcontractor of: (i) any Permit held in its name or (ii) any applicable Law, (d) any claims brought by Subcontractors against Owner claiming Contractor breach of contract with such Subcontractor including failure to make payments due and payable to such Subcontractor (except to the extent the same constitute Reimbursable Costs), (e) the

 

109


 

vitiation of any Contractor provided insurance policies due to Contractor’s or any Subcontractor’s breach of any representation, declarations or conditions contained in any insurance policy, including the provision of false or misleading information, (f) Contractor or any Subcontractor terminating the employment of or removing from the Work any employee who fails to meet the requirements set forth in Section 5.1.2 following a request by Owner to have such employee removed from Work, or (g) claims by any Government Authority as a result of a failure by Contractor or any Subcontractor to pay Taxes for which it is responsible to pay or remit under this Agreement.

30.1.3 To the fullest extent permitted by Law, Contractor assumes liability for, and agrees to indemnify, protect, save and hold harmless and defend each of the Owner Indemnitees from and against any and all Losses (including any strict liability, as well as reasonable attorneys’ fees, consultant fees, experts’ fees and litigation expenses) of whatsoever kind and nature that may be imposed on, suffered or incurred by or asserted against any Owner Indemnitee to the extent arising from the negligence of Contractor or any Subcontractor or any other Person directly or indirectly employed by any of them hereunder for damage to or loss of the physical property of Owner or its Affiliates for which Owner or its Affiliate has assumed care, custody and control (excluding, for the avoidance of doubt, the Work for which Contractor has the risk of loss under Section 25.2 at the time the damage occurred); provided, however, Contractor’s and Subcontractor’s total liability hereunder for each occurrence of such damage or loss to such property is capped at [***].

30.1.4 Notwithstanding anything to the contrary herein, no provision, clause, covenant, or agreement contained in, or collateral to this Agreement, will be understood to require Owner or Contractor to indemnify, defend, hold harmless, or have the effect of indemnifying, defending, or holding harmless, any indemnitee from or against any liability for loss or damage to the extent resulting from the Gross Negligence or Willful Misconduct of the indemnitee, an agent or employee of the indemnitee, or a third party over which the indemnitor has no control.

 

30.2

OWNER INDEMNITY.

Subject to Contractor’s indemnity obligations under Section 30.1, to the fullest extent permitted by Law, Owner assumes liability for, and agrees to indemnify, protect, defend, save and hold each of the Contractor Indemnitees harmless from and against any and all Losses (including any strict liability, as well as reasonable attorneys’ fees, consultant fees, experts’ fees and litigation expenses) of whatsoever kind and nature that may be imposed on, suffered or incurred by or asserted against any Contractor Indemnitee: (i) arising out of or due to a claim or action made by any third party (which third party shall not include any Contractor Indemnitee) to the extent caused by or arising directly from the negligence, Gross Negligence or Willful Misconduct of Owner, its Affiliates or Owner Contractors or their officers or employees while engaged in the performance of any activities in connection with this Agreement and (ii) for any claims arising out of Pre-Existing Hazardous Substances on the Job Site (except to the extent Contractor is otherwise liable as set forth in Section 30.1.2(a)(i)).

 

110


 

30.3

ACTIONS BY EMPLOYEES.

In any and all claims against any indemnified person by any employee of Contractor or any Subcontractor or by anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, the indemnification obligation stated above shall not be limited in any way by any limitation on the amount or type of damages, compensation or benefits payable by or for Contractor or any Subcontractor under the applicable workers’ compensation benefit acts, disability statute or other employee benefit acts.

 

30.4

NOTICE AND DEFENSE.

30.4.1 Subject to the foregoing provisions of this Article 30, within fifteen (15) days of receipt by an indemnified party under this Article 30 of notice of the commencement of any action, such indemnified party will, if a claim in respect thereof is to be made against the indemnifying party under Section 30.1 or Section 30.1.4 above, provide Notice to the indemnifying party of the commencement thereof. The indemnifying party shall have no liability under this Article 30 for any claim or action for which the indemnified party has admitted any liability or which such Notice is not provided to the extent that such failure to give Notice actually and materially prejudices the indemnifying party’s ability to defend against such claim. In case any such action is brought against any indemnified party and it provides Notice to the indemnifying party of the commencement thereof, the indemnifying party shall assume on behalf of such indemnified party, and conduct with due diligence and in good faith, the defense of any such action against such person, whether or not the indemnifying party is joined therein; provided, however, that, without relieving the indemnifying party of its obligations hereunder, the indemnified party may elect to participate, at its expense, in the defense of any such suit. The indemnifying party shall have the right to assume the defense of any such claim or action with counsel designated by the indemnifying party and reasonably satisfactory to the indemnified party, provided, however, that if the defendants in any such action include both indemnifying party and the indemnified party, and the indemnified party shall have reasonably concluded that there may be legal defenses available to it which are different from or additional to those available to the indemnifying party, the indemnified party shall have the right to select separate counsel to assert such legal defenses and to otherwise participate in the defense of such action on behalf of such indemnified party, the cost of which shall be subject to indemnification under this Article 30.

30.4.2 Should any indemnified party be entitled to indemnification under this Article 30 and should the indemnifying party fail to assume the defense of such claim or action, the indemnified party may, at the expense of the indemnifying party contest (or, with the prior consent of the indemnifying party, settle) such claim or action. No indemnifying party shall, without the prior written consent of the indemnified party, effect any settlement of any pending or threatened action in respect of which any indemnified party is or could have been a party and indemnity could have been sought hereunder by such indemnified party unless such settlement includes an unconditional release of such indemnified party from all liability on any claims that are the subject matter of such a pending or threatened action.

 

111


 

30.5

REMEDIES NOT EXCLUSIVE.

The rights of indemnity shall not be exclusive with respect to any other right or remedy provided for herein.

 

30.6

TAX EFFECT OF INDEMNIFICATION.

Notwithstanding anything to the contrary contained herein, any indemnity payments owed by a Party shall be reduced by any tax benefits to the indemnified Person and increased by any tax detriments to the indemnified Person resulting from such indemnity payment (including tax detriments resulting from any additional indemnity payments pursuant to the provisions of this Section 30.6), such tax benefits or detriments, if not mutually agreed by the Parties, to be determined by an independent, mutually agreed upon tax consultant.

 

31.

EVENTS OF DEFAULT; REMEDIES.

 

31.1

CONTRACTOR EVENTS OF DEFAULT.

Contractor shall be in default of its obligations under this Agreement if any of the following events arise or exist and is continuing and Contractor shall fail to remedy the same within [***] Days after Owner’s Notice of the occurrence of such event, or if such remedy cannot reasonably be completed in such time, Contractor shall fail promptly to commence and diligently (a) pursue remedial action within such period and (b) conclude such action as soon as practicable (and in any event within [***] Days after the occurrence of such event); provided, however, that (i) no such cure period shall be allowed as to Sections 31.1.1, 31.1.3, 31.1.4, 31.1.7, 31.1.8, and 31.1.16 and (ii) with respect to Sections 31.1.2, 31.1.6 and 31.1.9 the sole cure period shall be as set forth therein:

31.1.1 Contractor or any JV Member or Contractor Guarantor commences any case, proceeding or other action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of itself or its debts or assets, or adopts an arrangement with or makes an assignment for the benefit of creditors, under any bankruptcy, moratorium, rearrangement, insolvency, reorganization or similar law for the relief of creditors or affecting the rights or remedies of creditors in general or is declared insolvent or Contractor or any JV Member or Contractor Guarantor conceals or removes any part of its property with the intent to hinder, delay or defraud its creditors, or makes or suffers any transfer of its property which may be fraudulent under applicable Law, or admits in writing its inability to pay its debts; provided, however, any of the foregoing events affecting only a JV Member shall not be a Contractor event of default if and for so long as (i) Contractor is continuing to perform all of its obligations under this Agreement and (ii) the Contractor Guarantees remain in full force and effect and are unimpaired;

31.1.2 there shall be instituted against Contractor or any JV Member or Contractor Guarantor any case, proceeding or action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of Contractor or any JV Member or Contractor Guarantor or its debts or assets, which shall not have been terminated, stayed or dismissed within [***] Days after commencement, or a trustee, receiver, custodian or other like official is appointed for or to take possession of all or any part of the property or assets of Contractor or any JV Member or Contractor Guarantor, or Contractor or any JV Member or Contractor Guarantor generally does not pay its debts as they become due; provided, however, any of the foregoing events affecting only a JV Member shall not be a Contractor event of default if and for so long as (i) Contractor is continuing to perform all of its obligations under this Agreement and (ii) the Contractor Guarantees remain in full force and effect and are unimpaired;

 

112


 

31.1.3 Contractor assigns or transfers this Agreement or any of its rights or interests herein, except as expressly permitted hereunder, or a Contractor Guarantor assigns or transfers the Contractor Guarantee to which it is a party;

31.1.4 Contractor disregards or fails to comply with any Laws, Permit, Applicable Codes and Standards or any instruction regarding Contractor’s performance of the Work given by Owner’s Representative in writing in accordance with this Agreement;

31.1.5 any representation or warranty made by Contractor herein was materially inaccurate or misleading when made;

31.1.6 any Performance Security is not delivered to Owner within [***] Days of when due in accordance with this Agreement, or if delivered to Owner, expires or is terminated or repudiated, and is not replaced by Contractor as required in accordance with the express terms of this Agreement;

31.1.7 an Abandonment of the Project occurs;

31.1.8 Contractor, after a delay in or suspension of the Work permitted by this Agreement, fails or refuses to commence performance of the Work after the cessation of such delay or suspension as provided in Section 17.1;

31.1.9 Contractor fails to pay or cause to be paid any undisputed amount that is due and payable to Owner within [***] from the date such payment is due;

31.1.10 Contractor fails to maintain in full force and effect insurance policies of such types, in such amounts and with such deductibles, as are required pursuant to this Agreement;

31.1.11 Contractor fails to make prompt, undisputed payments when due to Subcontractors for labor, materials or equipment;

31.1.12 Contractor suspends performance of a material portion of the Work (other than as provided in Section 17.1.1, Section 17.1.3, Article 33 or pursuant to a Change Order);

31.1.13 Contractor defaults in its observance or performance of any of the terms, conditions and/or restrictions of Article 40;

31.1.14 Contractor fails to make good any Defects, Deficiencies or damage as described in Section 20.5;

31.1.15 Contractor fails to discharge or bond liens filed as required under this Agreement;

31.1.16 Contractor becomes legally domiciled in the State of Louisiana;

 

113


 

31.1.17 Contractor’s liability for any of LPS5 Schedule Delay Liquidated Damages, LPS6 Schedule Delay Liquidated Damages or Facility Substantial Completion Schedule Delay Liquidated Damages exceeds the LPS5 Schedule Delay Liquidated Damages Cap, LPS6 Schedule Delay Liquidated Damages Cap or Facility Substantial Completion Schedule Delay Liquidated Damages Cap, respectively;

31.1.18 Contractor ceases to be wholly-owned by the JV Members, collectively, for any reason, other than as the result of one JV Member having defaulted under the terms of the JV Agreement so long as at all times following such cessation due to such default: (a) Contractor continues to perform all of its obligations under this Agreement, and (b) the Contractor Guarantees remain in full force and effect and are unimpaired;

31.1.19 the JV Agreement is terminated as a result of the default of only one of the JV Members at any time prior to the end of the Warranty Period; provided that it shall not be a Contractor event of default if at all times following such termination: (a) Contractor continues in existence as a limited liability company under the laws of the State of Texas, (b) Contractor continues to perform all of its obligations under this Agreement and (c) the Contractor Guarantees are in full force and effect and unimpaired;

31.1.20 a Contractor Guarantor materially breaches its obligations under the Contractor Guarantee to which it is a party;

31.1.21 Contractor defaults in its observance or performance of any other material provision hereunder (except defaults for which the payment of liquidated damages is the sole and exclusive remedy as provided in Article 22); and

31.1.22 The Phase 1 Agreement is validly terminated by Owner as the result of an event of default by Contractor under the Phase 1 Agreement.

 

31.2

REMEDIES.

31.2.1 In the event that a Contractor default identified in Section 31.1 is continuing following the applicable cure periods described in Section 31.1.1, Owner shall have any or all of the following rights and remedies, and Contractor shall have the following obligations:

(a) Owner, without prejudice to any of its other rights or remedies under this Agreement, may unilaterally terminate this Agreement immediately by delivery of a Notice of termination to Contractor;

(b) If requested by Owner, Contractor shall withdraw from the Job Site, assign to Owner its rights and obligations under such Subcontracts as Owner may request, and remove such Materials, construction equipment, tools and instruments used by and any debris or waste materials generated by Contractor in the performance of the Work, and Owner, at its sole option, may enter onto the Job Site and take possession of all equipment, tools, supplies, scaffolding and machinery rented by Contractor, any and all designs, remaining Materials (and special tools comprising Materials), Subcontracts, correspondence, schedules, Deliverables and facilities of Contractor that Owner deems necessary to complete of the Work;

 

114


 

(c) Owner, without incurring any liability to Contractor, shall have the right (either with or without the use of the Materials, tools and instruments) to have the Work finished by itself or by another contractor; and

(d) Owner may recover amounts owing to it (as calculated in accordance with Section 31.3 below) by Contractor by enforcing its rights in respect of the Performance Security.

31.2.2 Owner may, without prejudice to any of its other rights or remedies, (a) seek performance by either or both of the Contractor Guarantors or any other guarantor of Contractor’s obligations hereunder, (b) seek equitable relief to cause Contractor to take action or to refrain from taking action pursuant to this Agreement, or to make restitution of amounts improperly received under this Agreement, (c) make such payments or perform such obligations as are required to cure such Contractor default, draw on or make a claim against any Performance Security or other security provided pursuant to this Agreement and/or offset the cost of such payment or performance against payments otherwise due to Contractor under this Agreement; provided that Owner shall be under no obligation to cure any such Contractor default or (d) seek damages as provided in Section 31.3, including proceeding against any bond, letter of credit or guarantee given by or for the benefit of Contractor for its performance under this Agreement.

 

31.3

DAMAGES.

In the event of any default by Contractor under Section 31.1 and termination by Owner of this Agreement pursuant to Section 31.2.1, Contractor shall, subject to Section 21.1, be liable to Owner for the amount of any costs and expenses reasonably incurred by Owner or any Person acting on Owner’s behalf in completing the Work and other expenses and fees related thereto in an attempt to achieve Final Completion by the Final Completion Deadline, or if such date has already passed, at the earliest possible date, less any amounts Owner would have been obligated to pay to Contractor as Total Costs hereunder in respect of completing such Work assuming this Agreement had not been so terminated (collectively, the “Cover Costs”), but only to the extent that (x) the aggregate sum of Cover Costs plus (i) all amounts paid or payable to Contractor under this Agreement prior to termination of this Agreement; plus (ii) amounts or costs paid or incurred by Owner prior to termination of this Agreement that have been included in the calculation of Total Costs pursuant to this Agreement, exceeds (y) the Target Price. See Exhibit B-3 for example calculations of Cover Costs. Owner shall be entitled to withhold further payments to Contractor until Owner determines or it is determined pursuant to the dispute resolution provisions set forth in Article 36 that Contractor is entitled to further payments. Promptly following Final Completion, the calculation of Cover Costs shall be determined by Owner, and Owner shall notify Contractor in writing of the amount, if any, that Contractor shall pay to Owner or Owner shall pay to Contractor, which amount shall be paid within thirty (30) Days of Notice from Owner.

31.4 OWNER REMEDIES.

Unless stated otherwise herein, the remedies of Owner set forth herein in respect of Contractor’s obligations and liabilities are in addition to any other remedies that might otherwise be available to Owner at law or in equity.

 

115


 

31.5

OWNER DEFAULT.

31.5.1 The following shall constitute a default by Owner:

(a) Subject to the provisions of this Agreement excusing such action, Owner shall fail to pay when due any undisputed amount under this Agreement and such failure shall continue uncorrected for a period for [***] Days after Notice thereof from Contractor;

(b) Owner commences any case, proceeding or other action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of itself or its debts or assets, or adopts an arrangement with or makes an assignment for the benefit of creditors, under any bankruptcy, moratorium, rearrangement, insolvency, reorganization or similar law for the relief of creditors or affecting the rights or remedies of creditors in general or is declared insolvent or Owner conceals or removes any part of its property with the intent to hinder, delay or defraud its creditors, or makes or suffers any transfer of its property which may be fraudulent under applicable Law, or admits in writing its inability to pay its debts;

(c) There has been instituted against Owner any case, proceeding or action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of Owner or its debts or assets, which shall not have been terminated, stayed or dismissed within [***] Days after commencement, or a trustee, receiver, custodian or other like official is appointed for or to take possession of all or any part of the property or assets of Owner, or Owner generally does not pay its debts as they become due; provided, however, that Owner shall have [***] Days to cure this default following Notice thereof from Contractor; and

(d) The Phase 1 Agreement is validly terminated by Contractor as the result of an event of default by Owner under the Phase 1 Agreement.

31.5.2 Contractor shall have the right to terminate this Agreement upon the occurrence of a default by Owner by delivery of a Notice of termination to Owner. Upon such termination, Contractor will be compensated (i) the Reimbursable Costs, Contractor’s G&A and Contractor’s Margin for all Work performed through the date of termination, and (ii) the reasonable costs to demobilize and any unavoidable cancellation charges from Subcontractors. Any such termination shall not relieve Contractor of its obligations to perform Corrective Work during any applicable Warranty Period.

 

31.6

OBLIGATIONS UPON TERMINATION.

31.6.1 Any termination of this Agreement (whether by Owner or Contractor) shall not relieve (a) Contractor and Owner of each of its obligations with respect to confidentiality as set forth herein, (b) any Party of any obligation hereunder which expressly or by implication survives termination hereof, (c) Owner of its obligation to pay amounts owing to Contractor pursuant to Section 31.5.2 and (d) any Party of its indemnity obligations or liabilities for loss or damage to another Party in accordance with this Agreement, and shall not relieve Contractor of its obligations and liabilities for the portions of the Work already completed prior to the date of termination.

 

116


 

31.6.2 Upon a termination of this Agreement pursuant to this Article 31 or Article 32: (a) Contractor shall leave the Job Site and remove from the Job Site all Contractor equipment, waste, rubbish and Hazardous Substances as Owner may request; (b) Owner shall take possession of the Job Site and of the Materials (whether at the Job Site, in transit or otherwise); (c) except as otherwise directed by Owner, Contractor shall promptly assign to Owner or its designee any contract rights (including warranties, licenses, patents and copyrights) that it, or any of its Subcontractors, has to any and all Materials, Deliverables and the Work, including contracts with Subcontractors and Contractor shall execute such documents as may be reasonably requested by Owner to evidence such assignment, subject to Owner’s assumption of same and, if required, Owner’s adequate assurance to such Subcontractors regarding Owner’s ability to pay; (d) to the extent so directed by the Owner, Contractor shall cancel as quickly as possible and upon terms satisfactory to Owner all orders placed by it with Subcontractors and shall use all reasonable efforts to minimize cancellation charges and other costs and expenses associated with the termination of this Agreement unless Owner elects to take assignment of any such Subcontracts; (e) Contractor shall cooperate with Owner for the efficient transition of the Work and thereafter shall use commercially reasonable efforts to execute that portion of the Work as may be necessary to preserve and protect Work already in progress and to protect Materials at the Job Site or in transit thereto, and to comply with any applicable Law, Permits and any Applicable Codes and Standards; (f) Contractor shall promptly furnish Owner with copies of all Deliverables, Auto CAD compatible electronic files, Drawings and Specifications and, to the extent available, final “as-built” drawings, in compliance with Exhibit J; (g) Contractor shall provide Owner and its designee with the right to use, free of charge, all other patented, copyrighted and other proprietary information or Intellectual Property relating to the Work that Owner deems necessary to complete the Work, and Contractor shall execute such documents as may be reasonably requested by Owner to evidence such right; (h) Contractor shall assist Owner in preparing an inventory of all Materials in use or in storage at the Job Site; and (i) Contractor shall take such other action as required hereunder upon termination of this Agreement. In the event that Contractor terminates this Agreement pursuant to and in accordance with Section 31.5.2, Contractor shall not be obligated to comply with paragraphs (c) through (h) (inclusive) of this Section 31.6.2(b) unless and until a Lender or another Person on behalf of Owner has cured, or has agreed in writing to cure, Owner’s default.

 

32.

TERMINATION FOR CONVENIENCE.

 

32.1

GENERAL.

32.1.1 Owner may in its sole discretion terminate the Work without cause at any time by giving Notice of termination to Contractor and such termination shall be effective upon the giving of such notice by Owner. If the Work is terminated by Owner without cause, Owner and Contractor shall have the following rights, obligations and duties:

(a) upon receiving any Notice of termination, Contractor shall stop performing the Work and, except for Subcontracts that Owner elects to take assignment of or as otherwise directed by Owner, shall cancel as quickly as possible all orders placed by it with Subcontractors and shall use all reasonable efforts to minimize cancellation charges and other costs and expenses associated with the termination of this Agreement;

(b) if Owner terminates the Work pursuant to this Section 32.1 after the issuance of a Limited Notice to Proceed, Contractor will be compensated for the Work performed under such Limited Notice to Proceed through the date of termination, plus reasonable costs to demobilize and any unavoidable and reasonable cancellation charges from Subcontractors under Subcontracts not assumed pursuant to Section 32.1.1(c); provided, however, that the amount payable for the Work actually completed by Contractor shall be subject to adjustment to the extent the Work requires Corrective Work;

 

117


 

(c) following a termination by Owner pursuant to this Section 32.1, Owner shall have the right, at its option, to assume and become liable for any reasonable written obligations and commitments that Contractor may have in good faith undertaken with third parties in connection with the Work, which obligations and commitments are not covered by the payments made to Contractor under Section 32.1.1(b). If Owner elects to assume any obligation of Contractor as described in this Section 32.1.1(c), then, as a condition precedent to Owner’s compliance with any section of this Article 32, Contractor shall execute all papers and take all other reasonable steps requested by Owner which may be required to vest in Owner all rights, set-offs, benefits and titles necessary to such assumption by Owner of such obligations described in this Article 32; and

32.1.2 Notwithstanding anything to the contrary contained herein, in the event Owner terminates this Agreement pursuant to this Article 32 for any reason prior to the issuance of a Limited Notice to Proceed or, if no Limited Notice to Proceed is issued, prior to the issuance of the Notice to Proceed, Contractor shall not be entitled to any remuneration from Owner.

 

32.2

CLAIMS FOR PAYMENT FOLLOWING TERMINATION FOR CONVENIENCE.

Any claim for payment by Contractor under this Article 32 must be made within sixty (60) Days after the effective date of a termination hereunder, and Owner’s payment thereof shall be made pursuant to the payment protocol set forth in Article 6.

 

33.

FORCE MAJEURE.

 

33.1

EXTENSION OF TIME FOR FORCE MAJEURE EVENT.

An equitable adjustment of the Target Price or any component thereof and of scheduled and guaranteed dates shall be granted to Contractor pursuant to a Change Order for a Force Majeure Event. The Parties acknowledge that this Agreement does not reflect the impact of the COVID-19 epidemic as of the Effective Date, if any. To the extent adverse impacts pertaining to the COVID-19 epidemic (such as those adversely affecting productivity) arise after the Notice to Proceed Date, each Party shall continue to work in good faith to mitigate any resulting impact, and shall be entitled, if and to the extent applicable, to relief pursuant to and in accordance with this Article 33.

 

33.2

CONTRACTOR’S RESPONSIBILITY.

33.2.1 Contractor shall work diligently to cure, remove, otherwise correct, minimize and contain all costs and expenses attendant on or arising from each Force Majeure Event including expenditures for avoidance or reduction of the effect of a Force Majeure Event. The failure of Contractor to perform such Work shall be reason for denial of the full extension of time, which would otherwise be justified. The extension of time for a Force Majeure Event shall be that duration of time jointly and reasonably determined by Owner, the Independent Engineer and Contractor to be reasonably necessary to make up the aggregate amount of time actually lost across all affected activities, all pursuant to the Change Order provisions of Article 12.

 

118


 

33.2.2 Contractor shall provide Notice of any Force Majeure Event to Owner and the Independent Engineer upon obtaining actual knowledge of the occurrence of such Force Majeure Event pursuant to and in accordance with Section 12.2.1.

 

33.3

CONTINUING RESPONSIBILITY OF CONTRACTOR.

If a Force Majeure Event occurs, Contractor shall remain responsible for completing the Work in accordance with the Project Schedule as adjusted pursuant to a Change Order.

 

33.4

PERFORMANCE NOT EXCUSED.

The payment of money owed shall not be excused because of a Force Majeure Event or Owner Caused Delay. In addition, neither Owner nor Contractor shall be excused under this Article 33 from timely performance of their obligations hereunder to the extent that a claimed Force Majeure Event was caused by any negligent or intentional acts, errors or omissions Willful Misconduct or for any breach or default of this Agreement by such Party. Furthermore, no suspension of performance or extension of time shall relieve the Party benefiting therefrom from any liability for any breach of the obligations that were suspended or failure to comply with the time period that was extended to the extent such breach or failure occurred prior to the occurrence of the applicable Force Majeure Event or Owner Caused Delay. Notwithstanding anything to the contrary contained herein, Contractor shall not be entitled to any adjustment to the Target Price in respect of demobilization and/or remobilization required as a result of any Force Majeure Event.

 

34.

DUTIES AND TAXES.

 

34.1

ALLOCATION OF RESPONSIBILITIES.

Contractor shall pay and administer, as Direct Costs, any and all Taxes payable in connection with the Work including, but not limited to Taxes imposed on services and Contractor’s purchase or rental of equipment, tools, and supplies used by Contractor in the performance of the Work, or the Materials incorporated into, installed in, or affixed or attached to the Facility; provided, however that any Taxes based on or related to the net income, capital or net worth of Contractor or any Subcontractor or Agent For Contractor shall be Non -Reimbursable Costs. Notwithstanding anything in the Agreement to the contrary, Owner shall be solely responsible for and shall, as required by applicable Law, pay the appropriate Government Authority all property taxes and other Taxes directly associated with: (i) its ownership and operation and maintenance of the Job Site, the Facility, and any Materials to be installed in, incorporated into, or affixed or attached to the Facility, and (ii) the supply of the Owner Furnished Equipment and Materials and performance of the Owner Scope of Work. Contractor shall reasonably cooperate with Owner to minimize any Taxes payable by Owner hereunder. If applicable, Owner shall timely provide Contractor: (i) a schedule identifying any portion of the Work eligible for exemption from Taxes; and (ii) a valid exemption certificate or any other documentation required by applicable Laws, demonstrating Owner’s eligibility for such exemption. Owner shall indemnify, defend, and hold Contractor harmless from and against all Taxes: (i) arising from disallowance of any exemption asserted by Owner under the Agreement; or (ii) Owner’s failure to comply with its Tax obligations under the Agreement.

 

119


 

34.2

LOUISIANA TAX AND INCENTIVES PROVISIONS.

Pursuant to state Law, certain tax and incentive programs are available to qualifying manufacturers in certain circumstances, including the Louisiana Quality Jobs Program, Enterprise Zone Program, and the Manufacturing Machinery and Equipment sales tax exclusion. Owner has not determined which, if any, of these programs it will pursue. Contractor shall reasonably cooperate with and assist Owner and any designated tax and incentive consultant, and shall require Subcontractors and Agent For Contractors to reasonably cooperate with and assist Owner and any designated tax and incentive consultant, in obtaining tax and incentive benefits under these and any other available programs. Such assistance may include, but is not limited to, documenting purchase transactions, providing reports and supporting documents required to be submitted to obtain the tax and incentive benefits, and acting as agent for Owner in connection with the purchase of manufacturing machinery and equipment.

 

35.

BINDING AGREEMENT; ASSIGNMENT.

 

35.1

BY OWNER.

The terms of this Agreement shall be binding upon Owner and its successors and assigns. Without the prior consent of Contractor, Owner may, upon prior written Notice to Contractor, assign all or part of Owner’s right, title and interest herein to any Lenders, any Affiliate of Owner, any successor to Owner’s business (whether by merger, acquisition or otherwise) or to any financially responsible assignee that agrees to be bound by the terms hereof. In addition, Owner may assign all or part of its right, title and interest herein to any other Person with the prior written approval of Contractor, which approval shall not be withheld unreasonably. Contractor acknowledges that the Lenders may under certain circumstances foreclose upon and sell, or cause Owner to sell or lease the Facility and cause any new lessee or purchaser of the Facility to assume all of the interests, rights and obligations of Owner arising under this Agreement. In such event, Contractor agrees to the assignment by Owner and the Lenders of this Agreement and its rights herein to such purchaser or lessee and shall release Owner and the Lenders from all obligations hereunder upon any such assignment, provided that such new lessee or purchaser assumes Owner’s obligations under this Agreement.

 

35.2

BY CONTRACTOR.

The terms of this Agreement shall be binding upon Contractor and its successors and permitted assigns, provided that assignment by Contractor of this Agreement or any partial or total interest therein without Owner’s and the Lenders’ prior written consent (at their sole and unfettered discretion) shall be null and void.

 

120


 

36.

DISPUTES.

 

36.1

DISPUTE RESOLUTION.

36.1.1 Any dispute, controversy or claim between the Owner and Contractor that arises out of, under or in connection with this Agreement, including its interpretation, performance, enforcement, termination, validity or breach (each a “ Dispute”) shall be subject to resolution under this Article 36, which shall be the exclusive dispute resolution method for any such Dispute. If Owner or Contractor wish to declare a Dispute they shall deliver to the other Party a written notice identifying the disputed issue (a “Notice of Dispute”).

36.1.2 Following the delivery of a Notice of Dispute, the Parties will attempt in good faith to resolve such Dispute promptly through negotiation. If the Dispute has not been resolved within thirty (30) days after the date on which the Notice of Dispute was delivered, then any Party shall be permitted to submit such Dispute to binding arbitration in accordance with Section 36.1.3.

36.1.3 Any Dispute that is not resolved pursuant to Section 36.1.2 shall be exclusively and definitively resolved through final and binding arbitration conducted in accordance with the Rules of Arbitration of the ICC, which (save as modified by this Section 36.1.3) are deemed to be incorporated by reference into this Section 36.1.3.

(a) The arbitration tribunal shall consist of three (3) arbitrators. One (1) arbitrator shall be appointed by Owner, one (1) arbitrator shall be appointed by Contractor, and the third arbitrator shall be selected by agreement of the first two (2) arbitrators. If either of the first two (2) appointments is not made within thirty (30) Days after the request for arbitration, or if the first two (2) arbitrators fail to agree on a third arbitrator within thirty (30) Days after the later of them has been appointed, the unfilled appointment will be made, at the request of either Owner or Contractor, by the ICC. No arbitrator appointed pursuant to this Section 36.1.3(a) shall be an employee, agent, competitor or former employee, agent or contractor of, or have or have had any material interest (directly or indirectly) in the business of or in any Party or any of its Affiliates. Each arbitrator shall be knowledgeable with respect to engineering, procurement and construction contracts and shall be fluent in the English language.

(b) Unless the Parties agree in writing otherwise:

(i) the seat of arbitration shall be New York, New York, and the language to be used in the proceedings shall be English;

(ii) the arbitrators shall, by majority vote, render a written award stating the reasons for their award within three (3) months after any hearing conducted has been concluded. The arbitral award may contain such orders (including orders for specific performance, setoff, other equitable relief or monetary damages) in respect of or affecting any of the Parties (and/or any Loss suffered by any of them), as such arbitral tribunal determines to be appropriate in the circumstances; provided that the arbitral tribunal shall not have the authority to award any indirect, consequential or punitive damages unless, but only to the extent, such damages are expressly permitted hereunder;

 

121


 

(iii) the Parties and the arbitral tribunal will ensure that the arbitration proceedings and any documents disclosed in such proceedings are kept strictly confidential;

(iv) the Parties may make an application to any court of competent jurisdiction for the obtaining of any evidence from third parties that the arbitrators direct may be relevant to the arbitral proceedings; and

(v) the responsibility for the costs of the arbitration will be determined by the arbitral tribunal.

(c) An arbitral award rendered in accordance with this Section 36.1.3 shall be final and binding on the Parties. The Parties agree that any arbitral award made pursuant to this Section 36.1.3 may be enforced against the Parties or their assets wherever they may be found and that a judgment upon the arbitral award may be entered (and any other applicable relief, including interlocutory relief, may be granted) in any court having jurisdiction on such matters, and subject to their respective obligations contained elsewhere herein, shall take all such actions as are necessary to give full and complete effect to the award which, in accordance with its terms, shall be binding upon and enforceable against them.

(d) No Party shall be entitled to suspend its performance under this Agreement during the pendency of any Dispute subject to this Section 36.1.3 or during the period during which any defaulting Party is attempting to remedy its non-performance of this Agreement within the periods prescribed therefor in Article 31.

(e) Nothing contained in this Article 36 shall be construed to prohibit any Party from making an application to any court of competent jurisdiction for an order of specific performance or for other injunctive or equitable relief as long as the arbitral tribunal contemplated in this Section 36.1.3 has not yet been formed.

36.1.4 Unless the Parties otherwise agree, no dispute, controversy or claim hereunder shall be consolidated with any other arbitration proceeding involving any third party.

 

36.2

CONTINUATION OF WORK DURING DISPUTE.

Notwithstanding any Dispute, it shall be the responsibility of Contractor to continue to prosecute all of the Work diligently and in a good and workmanlike manner in conformity with this Agreement. Except to the extent provided in Section 31.5.2, Contractor shall have no right to cease performance hereunder or to permit the prosecution of the Work to be delayed. Owner shall, subject to its right to withhold or offset amounts pursuant to this Agreement, continue to pay Contractor undisputed amounts in accordance with this Agreement; provided, however, in no event shall the occurrence of any negotiation or arbitration prevent or affect Owner from exercising its rights under this Agreement, including Owner’s right to terminate pursuant to Sections 31.2 and 32.1.1.

 

122


 

37.

INDEPENDENT CONTRACTOR.

 

37.1

GENERAL.

Contractor is an independent contractor and nothing contained herein (including Section 24.5) shall be construed as constituting any relationship with Owner other than that of owner and independent Contractor, nor shall it be construed as creating any relationship whatsoever between Owner and the Contractor’s employees. Neither Contractor nor any of its employees is or shall be deemed to be employees of Owner. Contractor shall not have the authority to act on behalf of Owner or to bind Owner in any manner, except as expressly set forth herein.

 

37.2

EMPLOYEES.

Subject to Section 5.2 and Article 24 hereof, Contractor has sole authority and responsibility to employ, discharge and otherwise control its employees.

 

37.3

RESPONSIBILITY FOR SUBCONTRACTORS, ETC.

Contractor accepts complete responsibility for the acts of its agents, employees, Agent For Contractors, Subcontractors and all others it hires to perform or assist in the performance of the Work.

 

38.

NOTICES AND COMMUNICATIONS.

 

38.1

REQUIREMENTS.

38.1.1 Any Notice, request, proposal for changes, Change Order, and correspondence (including drawings, lists, schedules, instruction books, or statements) required or permitted under the terms and conditions of this Agreement shall be in writing and (a) delivered personally, (b) sent by e-mail with the receiving Party retaining a confirmation receipt (and confirming receipt thereof to sender with respect to non-routine materials), (c) sent by a recognized overnight mail or courier service, with delivery receipt requested (with respect to non-routine materials) or (d) sent by mail (return receipt requested with respect to non-routine materials), to the following addresses (or to such other address that the receiving Party may designate from time to time in accordance with this Article 38); provided, however, Requests for Payment (excluding lien waivers) need only be sent as PDF documents by e-mail in the manner described in sub-section (b):

If to Contractor:

 

123


 

If to Owner:

38.1.2 Promptly after the occurrence of the Financial Closing Date, Owner shall provide to Contractor the details for the delivery of Notices under this Agreement to the Independent Engineer and the representative(s) for the Lenders.

 

38.2

EFFECTIVE TIME.

A Notice delivered in accordance with Section 38.1 shall be deemed to have been delivered upon the receipt thereof.

 

38.3

TECHNICAL COMMUNICATIONS.

Any technical or other communications pertaining to the Work shall be between the Contractor’s Representative and Owner’s Representative or other representatives appointed by the Parties. Each Party shall give Notice to the other of the name of such representative or representatives. The Contractor’s Representative shall be satisfactory to Owner, have knowledge of the Work and be available at all reasonable times for consultation.

 

124


 

39.

FINANCING MATTERS.

Owner contemplates obtaining financing (including any refinancing thereof) for the Facility consisting of one or more construction or permanent loans to be secured by all or a portion of the Facility and its rights under this Agreement and certain equity contributions (the “Financing”). In the event Owner applies for or obtains any Financing, Contractor shall, notwithstanding the existence of any Dispute between the Owner and Contractor, promptly execute or consent to a Consent and Agreement in the form attached hereto as Exhibit F-5 (the “Consent and Agreement”), including any additional terms or provisions reasonably requested by any of the Lenders, an Indemnity Undertaking in favor of the title insurance providers in the form attached hereto as Exhibit F-14 from each of Contractor and each Contractor Guarantor, and such other documents, which are reasonably required by the Lenders in connection with such Financing and which are in form and substance reasonably acceptable to the Parties (collectively, the “Financing Deliverables”); provided, however, that Contractor shall have a reasonable period of time prior to the execution of each Financing Deliverable within which to review any such documents. So long as the Lenders’ requested terms or provisions do not materially change or impact the terms of this Agreement, they shall be deemed reasonable. Contractor shall respond to reasonable requests by the Lenders for certificates and legal opinions as well as information regarding the qualifications, experience, past performance and financial condition of Contractor and other matters pertaining to Contractor’s participation hereunder and in the Facility. Contractor’s obligations under this Article 39 shall extend until at least the end of the Warranty Period.

 

40.

COMPLIANCE WITH LAWS.

 

40.1

ANTI-CORRUPTION.

40.1.1 Contractor represents, warrants and covenants that neither it, nor any of its Affiliates (or any of their respective principals, partners or funding sources), is currently (a) a Person designated by the U.S. Department of Treasury’s Office of Foreign Assets Control as a “specially designated national or blocked person” (“SDN”) or similar status, (b) a person otherwise identified by a government or legal authority as a person with whom Owner is prohibited from transacting business, (c) directly or indirectly owned or controlled by an SDN or the government of any country that is subject to an embargo by the government of the United States of America or (d) a Person acting on behalf of an SDN or a government of any country that is subject to an embargo by the government of the United States of America. Contractor agrees that it will notify Owner in writing immediately upon the occurrence of any event that subsequently results in any of the designations set forth in this Section 40.1.1.

40.1.2 Each Party shall, in the performance of this Agreement, comply with all laws, orders, directives, and regulations in effect on the Effective Date and as they may be amended from time to time that are applicable to the Party. Notwithstanding anything to the contrary contained herein, this Agreement shall not be interpreted or applied so as to require a Party to do, or to refrain from doing, anything that would constitute a violation of federal or state laws and regulations applicable to it, including the Foreign Corrupt Practices Act of 1977, 15 U.S.C. § 78dd-2, the OECD Anti-Bribery Convention, the U.K. Bribery Act of 2010, E.U. and E.U. member country anti-bribery and corruption laws, laws or regulations restricting participation in or compliance with certain foreign boycotts, directly or indirectly, as contained in the U.S. Export

 

125


 

Administration Act of 1979, the U.S. Internal Revenue Code or any similar statute, regulation, order or convention binding on the Party, as each may be amended from time to time, and including implementing regulations promulgated pursuant thereto (collectively, the “Anti-Corruption Laws”). Without limiting the foregoing, each Party agrees on behalf of itself, its Affiliates and their respective directors, officers, employees, agents and contractors, not to pay any fees, commissions or rebates to any employee, officer or agent of the other Party or its Affiliates or their respective shareholders, or provide or cause to be provided to any of them any gifts or entertainment of significant cost or value in connection with this Agreement or in order to influence or induce any actions or inactions in connection with the commercial activities of the Parties in connection with this Agreement. Each Party further agrees to cooperate and conduct its business and activities pursuant to this Agreement in such a manner to ensure that no Party or any of their respective Affiliates is placed in a position of non-compliance with federal and state laws and regulations applicable to it, including any reporting requirements.

40.1.3 Contractor represents, warrants and covenants with respect to itself and its Affiliates that, except as disclosed by a Contractor Guarantor in public filings with the U.S. Securities and Exchange Commission (a) it and its Affiliates are being and have been operated in compliance in all material respects with the Anti -Corruption Laws, (b) neither it nor any of its Affiliates has received any written notice or claim alleging any material violation under any of the Anti-Corruption Laws, and (c) neither it nor any of its Affiliates, nor any of their respective directors, officers, or employees (or, to the best of Contractor’s knowledge and belief, any partner, intermediary or other Person acting or purporting to act on behalf of such party or any of its Affiliates) has knowingly directly or indirectly paid, offered, given, promised to pay or authorized the payment of any money or anything of value to (i) any candidate for public office, any past or present employee, director, officer, official, representative or agent of any government, government or legal authority, instrumentality, or any public international organization (“Government Official”), (ii) any Person acting for or on behalf of any Government Official, or (iii) any other Person at the suggestion, request, direction or for the benefit of any of the above-described Persons to obtain, retain or direct business or to obtain special concessions or pay for favorable treatment for business secured or for special concessions already obtained.

40.1.4 Neither Contractor nor any of its Affiliates, directors, officers, employees or agents, shall use its relationship with Owner to attempt to disguise the sources of illegally-obtained funds. Contractor further represents and warrants that no such attempt of the sort described in this Section 40.1.4 has been made prior to the Effective Date.

 

40.2

RECORDS.

Contractor shall keep all records necessary to confirm compliance with Sections 40.1.1 through 40.1.4 for a period of five (5) years following the year for which such records apply. If Owner asserts that Contractor is not in compliance with Section 40.1.1, Section 40.1.2, Section 40.1.3 or Section 40.1.4, Owner shall send Notice to Contractor indicating the type of non-compliance asserted. After giving such Notice, Owner may cause an independent auditor to audit the records of Contractor in respect of the asserted non-compliance. The costs of any independent auditor under this Section 40.2 shall be paid (a) by Contractor, if Contractor is determined not to be in compliance with Section 40.1.1, Section 40.1.2, Section 40.1.3 or Section 40.1.4 or (b) by Owner, if Contractor is determined to be in compliance with Section 40.1.1, Section 40.1.2, Section 40.1.3 and Section 40.1.4.

 

126


 

40.3

EXPORT CONTROLS.

40.3.1 The Parties agree to comply with all applicable United States (“U.S.) and non-U.S. export control and economic sanctions laws in the performance of this Agreement, including any restrictions or conditions regarding the export, re-export, or other transfer of the Deliverables that are in effect now or are hereafter imposed by the U.S. or other Government Authority. Each Party shall be responsible for its own compliance with applicable export control and economic sanctions laws with regards to their Affiliates, employees, facilities and activities. These restrictions and conditions include (a) restrictions and export licensing requirements governing the export, re-export, or other transfer to other persons, entities, or countries of the Deliverables, (b) restrictions and export licensing requirements governing the export or other transfer of foreign-developed information that incorporates the Deliverables, (c) any applicable U.S. and other restrictions on the export, re-export, or other transfer of the Deliverables to countries, entities and persons that are subject to U.S. or other applicable sanctions, embargoes, or other prohibitions and (d) any applicable U.S. or other restrictions on the export or other transfer of the direct product of U.S. or other origin technical data (collectively, the “Export Controls”). Contractor shall provide Owner written Notice prior to transferring any Deliverable, commodity, software or technology that is: (i) controlled at a level greater than EAR99 under the Export Administration Regulations (“EAR”); or (ii) subject to the jurisdiction of an export control regime other than the EAR.

40.3.2 Each Party acknowledges that the other Party would not have an adequate remedy at law for money damages if the covenants contained in this Section 40.3 were breached and that any such breach would cause the other Party irreparable harm. Accordingly, each Party agrees that, in the event of any breach or threatened breach of the terms of this Section 40.3 by such Party, the other Party, in addition to any other remedies that it may have, shall be entitled, individually or jointly, without the requirement of posting a bond or other security, to equitable relief, including injunctive relief and specific performance.

 

40.4

SUBCONTRACTORS; INDEMNIFICATION.

40.4.1 Contractor agrees that with regard to any activities conducted pursuant to this Agreement, it will require its Subcontractors to agree to and comply with contractual provisions substantially equivalent to those contained in this Article 40.

40.4.2 Contractor agrees to indemnify and hold Owner, the Owner’s Affiliates and their respective shareholders, directors, officers, employees, agents, consultants or representatives harmless from any claims by Government Authorities for fines and penalties arising out of Contractor’s violation of Anti-Corruption Laws or Export Controls.

 

127


 

41.

MISCELLANEOUS.

 

41.1

FURTHER ASSURANCES AND EXPENSES.

The Parties undertake to act fairly and in good faith and use their reasonable efforts in relation to the performance and implementation of this Agreement and to take such other reasonable measures as may be necessary for the realization of its purposes and objectives, including, at the request of another Party, without further consideration, promptly executing and delivering or causing to be executed and delivered to such Party such assistance, or consents or other instruments in addition to those required by this Agreement, in form and substance satisfactory to such Party, as such Party may reasonably deem necessary or desirable to implement anything contained herein. Each Party shall pay its own costs and expenses in relation to the negotiation, preparation, execution and carrying into effect of this Agreement and the JV Agreement which, in the case of Contractor, constitute Non-Reimbursable Costs hereunder.

 

41.2

RECORD RETENTION.

Contractor agrees to retain for a period of five (5) years from the date of Final Completion all records relating to its performance of the Work, and to cause all Subcontractors and Agent For Contractors engaged in connection with the Work to retain for the same period all their records relating to the Work.

 

41.3

NO WAIVER.

No waiver of any of the terms and conditions of this Agreement shall be effective unless in writing and signed by the Party against whom such waiver is sought to be enforced. Any waiver of the terms hereof shall be effective only in the specific instance and for the specific purpose given. The failure of a Party to insist, in any instance, on the performance of any of the terms and conditions hereof shall not be construed as a waiver of such Party’s right in the future to insist on such performance.

 

41.4

SEVERABILITY.

The invalidity or unenforceability, in whole or in part, of any portion or provision of this Agreement will not affect the validity or enforceability of any other portion or provision hereof. Any invalid or unenforceable portion or provision shall be deemed severed from this Agreement and the balance of this Agreement shall be construed and enforced as if this Agreement did not contain such invalid or unenforceable portion or provision; provided, however, the Parties agree to negotiate in good faith to replace the invalid or unenforceable provision with a valid and enforceable provision that will, to the extent possible, preserve the intended economic positions of the Parties.

 

41.5

BINDING ON SUCCESSORS.

This Agreement shall be binding on the Parties hereto and on their respective successors, heirs and permitted assigns.

 

128


 

41.6

GOVERNING LAW.

41.6.1 THIS AGREEMENT SHALL IN ALL RESPECTS BE GOVERNED BY, AND CONSTRUED IN ACCORDANCE WITH THE LAW OF THE STATE OF NEW YORK WITHOUT REGARD TO PRINCIPLES OF CONFLICTS OF LAWS. Each of the Parties hereby submits to the non-exclusive jurisdiction of the federal courts or state of New York courts with venue in the State of New York for the purposes of all legal proceedings arising out of or relating to this Agreement or the transactions contemplated hereby. Each of the Parties irrevocably waives, to the fullest extent permitted by applicable Law, any objection that it may now or hereafter have to the laying of the venue of any such proceeding brought in such a court and any claim that any such proceeding brought in such a court has been brought in an inconvenient forum. The Parties agree that a judgment in any suit, action or proceeding in such a court shall be conclusive and may be enforced in other jurisdictions by suit on the judgment or by any other manner provided by law, and each of the Parties waives any defense or objection they may have regarding the validity or enforceability of any such judgment; provided, however, that such judgment shall not constitute a waiver of any rights of appeal. Nothing in this Section 41.6 shall be deemed to modify the provisions of Article 36.

41.6.2 EACH OF THE PARTIES HEREBY IRREVOCABLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY AND ALL RIGHT TO TRIAL BY JURY IN ANY LEGAL PROCEEDING ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY.

 

41.7

SET-OFF.

Notwithstanding anything to the contrary contained herein, any and all amounts owing or to be paid by Owner to Contractor hereunder, shall be subject to offset and reduction in an amount equal to any amounts that may be owing at any time by Contractor to Owner hereunder. Further, for the avoidance of doubt, with respect to anything contained herein that allows Owner to offset, set-off or draw against any Performance Security any amount then owed to Contractor, Owner shall have the express right to include in the amount offset, set-off or drawn under such Performance Security all of the reasonable costs and expenses it incurs in connection with enforcing such provision (including reasonable attorneys’ and other consultants’ fees).

 

41.8

AMENDMENT.

No amendment, modification or supplement of or to this Agreement shall be binding and effective unless in writing and signed by all of the Parties.

 

41.9

HEADINGS FOR CONVENIENCE ONLY.

The headings of the various sections contained herein are not part of this Agreement and are included solely for convenience of the Parties.

 

129


 

41.10

NONDISCRIMINATION.

Contractor agrees for and on behalf of itself and the JV Members that in the performance of the Work under this Agreement, it will not knowingly violate any applicable Laws prohibiting discrimination in employment.

 

41.11

COUNTERPART EXECUTION.

This Agreement may be executed by the Parties in any number of counterparts (and by each of the Parties on separate counterparts), each of which when so executed and delivered shall be an original, but all such counterparts shall together constitute but one and the same instrument. The .pdf or electronic signatures of the Parties shall be deemed original signatures, and .pdf or electronic copies hereof shall be deemed to constitute duplicate originals.

 

41.12

THIRD-PARTY BENEFICIARIES.

Except with respect to the rights of successors and permitted assigns as provided herein, any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders) and the rights of indemnitees under Article 30, (a) nothing contained herein nor any action taken hereunder shall be construed to create any duty, liability or standard of care to any Person that is not a Party, (b) no person that is not a Party shall have any rights or interest, direct or indirect, in this Agreement or the services to be provided hereunder and (c) this Agreement is intended solely for the benefit of the Parties, and the Parties expressly disclaim any intent to create any rights in any third party as a third-party beneficiary to this Agreement or the services to be provided hereunder.

 

41.13

SURVIVAL OF OBLIGATIONS.

Notwithstanding anything to the contrary contained herein, any termination of this Agreement shall not relieve (a) any Party of its obligations with respect to confidentiality as set forth herein, (b) any Party of any obligation hereunder which expressly or by implication survives termination hereof (including the provisions of Articles 17, 21, 24, 29, 30, 36 and 41 and Section 6.4) and (c) any Party of its obligations or liabilities for loss or damage to another Party arising out of or caused by acts or omissions of such first Party prior to the effectiveness of such termination or arising out of such termination, and shall not relieve Contractor of its obligations and liabilities for the portions of the Work already performed prior to the date of termination.

 

41.14

ENTIRE AGREEMENT.

This Agreement embodies the entire agreement among the Parties relating to the specific subject matter hereof and supersedes all prior written agreements regarding the subject matter hereof. The Parties shall not be bound by or liable for any documents proposed or submitted prior to the Effective Date and not incorporated into (by reference or otherwise) or referred to in this Agreement, or by or for any statement, representation, promise, inducement or understanding of any kind or nature relating to the Work or any other matter covered by this Agreement which is not set forth or provided for herein. All waivers, releases, exclusions of and limitations on liability and remedies expressly stated herein shall apply to the Parties and their respective Affiliates and employees, regardless of whether arising in contract, warranty, tort (including negligence),

 

130


 

statutory or strict liability or otherwise. Without limiting the generality of the foregoing, in no event shall (x) this Agreement be construed or interpreted to amend, modify or supplement the Phase 1 Agreement or (y) the Phase 1 Agreement be construed or interpreted to amend, modify or supplement this Agreement, in each case in any respect.

 

41.15

RELATIONSHIP.

Nothing contained herein shall be deemed to constitute, create, give effect to, constitute any commitment to, or otherwise recognize or contemplate a joint venture, partnership or formal business entity of any kind, and the rights and obligations of the Parties shall be expressly limited only to those expressly set forth herein. There shall be no other or implied obligations hereunder.

 

41.16

LIMITED RECOURSE.

The Parties’ sole recourse for any damages or liabilities due pursuant to this Agreement shall be limited to the remedies provided under the Contractor Guarantees, the Performance Security and the assets of the other Party and, except as provided in the Contractor Guarantees, without recourse individually or collectively to the assets of the members or the Affiliates of any other Party, the Lenders or their respective directors, agents, members, shareholders, managers, employees, representatives, partners and officers.

[Signatures appear on the following page]

 

131


 

IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed by their duly authorized representatives as of the Effective Date.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC
By:  

/s/ Keith Larson

Name:   Keith Larson
Title: Secretary
KZJV LLC
By:  

/s/ Paul Fellows

Name: Paul Fellows
Title:   Manager
By:  

/s/ Matt Key

Name: Matt Key
Title:   Manager

[Phase 2 EPC Agreement Signature Page]


 

Execution Version

EXHIBIT A

SCOPE OF WORK; APPLICABLE CODES AND STANDARDS

[Omitted]

 

1


 

Execution Version

EXHIBIT B-1

DIRECT COSTS AND NON-REIMBURSABLE COSTS

 

1.

Direct Costs.

1.1 Direct Costs are comprised of Direct Labor Costs and Other Direct Costs.

1.1.1 “Direct Labor Costs” means the Non-Craft Direct Labor Costs and the Craft Direct Labor Costs, in each case, incurred by Contractor with respect to the performance of the Reimbursable Work, excluding in all cases any Non-Reimbursable Costs.

 

  (a)

Non-Craft Direct Labor Costs” or “Staff” as used herein means, with respect to each category of Contractor’s non-craft employees identified in Exhibit C and the Personnel Authorization Assignment Form (PAAF), (i) the actual, verifiable and documented hours worked by such Contractor non-craft employees in the performance of the Reimbursable Work multiplied by (ii) the applicable rates set forth in Exhibit C for such Contractor non-craft employees.

 

  (b)

Craft Direct Labor Costs” means, with respect to each category of Contractor’s craft employees identified in Exhibit C and the Personnel Authorization Assignment Form (PAAF), (i) the actual, verifiable and documented hours worked by such Contractor craft employees in the performance the Reimbursable Work multiplied by (ii) the applicable rates set forth in Exhibit C for such Contractor craft employees.

1.1.2 “Other Direct Costs” means the actual, verifiable and documented expenditures, other than (i) Direct Labor Costs and (ii) Contractor’s G&A (described in Section 3 below), incurred by Contractor while performing the Reimbursable Work, excluding in all cases any Non-Reimbursable Costs. Other Direct Costs include all costs incurred in connection with the Work including, without limitation, the following items, without duplication, unless such items are expressly stated to be Non-Reimbursable Costs:

 

  (a)

Facility expenses (including all payments made by Contractor to Subcontractors in connection with the performance of the Reimbursable Work), less amounts reimbursed or credited to Contractor by Subcontractors (including back charges for Work performed by Contractor to complete Subcontractor work or remedy Subcontractor Defects and Deficiencies, liquidated damages or otherwise);

 

  (b)

the cost of all Materials, plus related transportation, temporary storage for logistics receiving, protection and preservation, services of freight forwarding agents including logistics, boxing, packing, export preparation, customs clearance and import duties required for the performance of the Reimbursable Work;

 

1


 

Execution Version

 

  (c)

the cost of Permits required to be obtained by Contractor in the performance of the Reimbursable Work;

 

  (d)

the costs of third party consultants, subject to Owner’s prior approval (such approval not to be unreasonably withheld), and of manufacturers’ supervisors, service and commissioning engineer / technicians and vendor service representatives required by Contractor to perform the Reimbursable Work;

 

  (e)

the cost of inspection fees or other fees paid to Government Authorities or third party inspectors, required by Government Authorities to be paid by Contractor in the performance of the Reimbursable Work;

 

  (f)

Contractor Taxes as provided for in Section 34.1 of the Agreement;

 

  (g)

Specialized computer software or licenses, subject to Owner’s prior approval;

 

  (h)

all costs incurred by Contractor for repairing or replacing Defects or Deficiencies as provided for in Section 20.1.1 of the Agreement, including Subcontractor costs to repair or replace Defects or Deficiencies (to the extent payable to Subcontractors) and the cost of the enforcement of Subcontractor warranties with respect to the Reimbursable Work;

 

  (i)

all costs incurred by Contractor for remedying physical damage to the Reimbursable Work or the property of Owner, its Affiliates, Owners Contractors, subcontractors and vendors and any and all costs to remove and reinstall the same;

 

  (j)

currency forward contracts, hedges and options entered into by Contractor with Owner’s prior approval solely with respect to the performance of the Reimbursable Work;

 

  (k)

Contractor staff and craft relocation costs (in accordance with Contractor’s relocation policy, as provided to Owner in writing and approved by Owner (such approval not to be unreasonably withheld), cost of living adjustment, uplifts, incentives, travel and subsistence expenses, per diem, safety and performance incentives, in each case, only if such costs were incurred by Contractor in connection with the performance of the Reimbursable Work;

 

  (l)

Staff travel expenses reasonably required to perform the Reimbursable Work, including temporary duty costs, audits, and meetings at the Job Site or Owner’s offices. Travel costs for international travel that is required to perform the Reimbursable Work shall be pre-authorized by Owner. Travel shall be consistent with Contractor standard procedures, Owner Standards and subject to the following requirements:

 

  (1)

travel policies approved by Owner;

 

2


 

Execution Version

 

  (2)

travel time shall be billed at the applicable labor billing rate set forth in Exhibit C and the Personnel Authorization Assignment Form (PAAF), unless pre-authorized in writing by Owner; and

 

  (3)

mileage for personal vehicles shall be billed per Contractor’s normal mileage reimbursement policy.

 

  (m)

All office space not located at or adjacent to the Job Site provided by Contractor to Owner or any Owner Contractor using the rates set forth in Exhibit C;

 

  (n)

Job Site infrastructure, offices, lay down areas, temporary facilities (including offices, furnishings, fixtures, utilities, sewer, firewater systems and water), lunchrooms, craft support, facilities, safety facilities, safety and QA/QC equipment and testing apparatus, security, first aid, site cleaning or clearing as required, trash disposal, sanitary facilities, janitorial services, photography, model photographs, general drawing and office supplies (including but not limited to paper, pencils, pens, file folders, printed forms, stationary, paper cutters, staplers, drawing racks and computer discs), communications, reproduction or other graphic services, copy machines (including installation and maintenance) and all other equipment, materials, and specialty items and services required to complete the Reimbursable Work;

 

  (o)

Hourly rates or unit rates, as specified in Exhibit C, incurred in connection with Reimbursable Work including module fabrication, ship offloading (of Owner Furnished Equipment and Materials and Agent-For Equipment and Materials) and barge transfer of modules to barges for transport to the Job Site. Hourly rates and unit rates shall apply equally and without adjustment to performance of all Work, regardless of (i) large or small quantities, (ii) elevations, (iii) positions within any applicable Facility module or component, (iv) location within the Job Site, (v) accessibility, (vi) constraints of the work permit system and Commissioning activities or (vii) and any other factor that would affect productivity in the completion of the applicable Work, including Work executed on transportation barges;

 

  (p)

Contractor and Subcontractor cost of construction equipment, including equipment on standby as defined in the Facility equipment plan and equipment for Pre-Commissioning, Commissioning and start-up at the Job Site, required to perform the Reimbursable Work. Owner approval shall be required for the Facility equipment plan and any stand-by other than short term stand-by of equipment; when stand-by is not approved then demobilization and remobilization costs shall be applicable. All Contractor owned equipment shall be charged at the rates set forth in Exhibit C. Construction equipment charges shall be consistent with the following:

 

  (1)

mobilization and demobilization expenses (including unavoidable cancellation charges from Subcontracts upon termination) will be charged to Owner at the cost incurred by Contractor for equipment in the Mobilization Plan that is approved by Owner (such approval not to be unreasonably withheld);

 

3


 

Execution Version

 

  (2)

each of (i) tires and tracks using the rates set forth in Exhibit C, (ii) labor and materials for long-term maintenance repairs and other service and repairs, and (iii) fuel, oil, and grease;

 

  (3)

Operators are not included in the stated rates for equipment;

 

  (4)

Third party rentals will be invoiced at cost;

 

  (5)

equipment will not be overhauled/painted prior to removal from the Job Site; and

 

  (6)

Contractor equipment assigned to the Work will be charged to Owner, and shall not exceed 50 hours per week for the first shift unless approved by Owner. Equipment utilized on the approved equipment plan on a second shift shall be billed shall not exceed 20 hours per week unless approved by Owner. To the extent that equipment is equipped with a smart meter that shows actual utilization, and the meter shows utilization of hours in excess of 50 hours for day shift and 20 hours for night shift if assigned, the equipment will be billed based on the actual meter hours. Equipment that is expected to have smart meters includes but not is limited to cranes, dozers, back hoes, roller/vibrators. Equipment charges apply to equipment which is verifiable and documented that is on standby for Work, Owner shall be notified weekly of all equipment on stand-by. To the extent the Contractor decides to pre-stage equipment prior to use, mobilizes equipment without prior Owner authorization, or equipment is stored on the Job Site prior to removal, neither storage nor equipment utilization will be invoiced. Contractor shall notify Owner of all pre-stage or stored equipment on the Job Site. Contractor shall provide a copy of the approved Mobilization Plan, proof of equipment utilization in the form of weekly equipment utilization summary timesheets signed by authorized Owner personnel for all equipment utilized. In the event equipment is approved for standby by Owner, equipment charges, as set forth in Exhibit C, shall apply. In order to substantiate equipment charges in Contractor’s invoice, Contractor shall provide proof of standby authorization, and provide weekly summary timesheet signed by Company authorized personnel for all equipment on standby.

 

  (q)

commodities, supplies, rental tools, loss or damage to tools not included with ST&S, re-assembly of equipment after inspections or transportation, consumables, skip boxes, scaffolding replacement components, Connex and freight containers, and personnel protective equipment;

 

  (r)

costs of commercial testing and inspection laboratories, soils testing and analysis consultants, x-ray testing/NDE/NDT, concrete and soil testing, stress relieving kits and supplies, etc. and similar third-party services required for the performance of the Reimbursable Work;

 

4


 

Execution Version

 

  (s)

rental costs for vehicles for Contractor personnel necessary for the performance of the Reimbursable Work, only if such rental costs were incurred in compliance with Contractor’s vehicle rental policy, Owner’s Standards and per Owner’s prior approval with respect to any changes to the vehicle rental policy or equipment plan. Aggregate rental costs for any vehicle shall not exceed the vehicle’s fair market value;

 

  (t)

Hazardous Substance cleanup, subject to the limitations set forth in Section 3.8.46 and Section 30.1.2 of the Agreement;

 

  (u)

miscellaneous Job Site expenses necessary to perform the Reimbursable Work, including expenses to acquire, purchase, lease or pay for furniture, phones, copiers, printers, plotters, facsimile equipment, mail service, internet service, computers, training materials and equipment, networks, courier services, internal and external photocopying, related petty cash items, temporary facilities and supplies, utilities, miscellaneous Job Site services, specialty software requested by Owner or not normally used by Contractor and software maintenance (so long as notified to Owner prior to use);

 

  (v)

Facility-specific entertainment and incentives consistent with Contractor policies, with any expense exceeding [***] per event requiring Owner’s prior approval;

 

  (w)

consumable spares and fluid fills of lubricants, all liquids and chemicals such as catalysts, chemicals, water, nitrogen, coolants, greases, lubricants, refrigerants and any topping off of these items and similar supplies, in each case required for construction, Pre-Commissioning, Commissioning and start-up;

 

  (x)

Safety supplies and equipment (including PPE) for the Reimbursable Work;

 

  (y)

costs incurred in replacing operating and Commissioning Spare Parts borrowed from Owner’s inventory (excluding Spare Parts used in connection with Corrective Work);

 

  (z)

costs incurred in obtaining and maintaining Facility-specific insurance policies required under the Agreement;

 

  (aa)

costs of Facility-specific project attorney personnel hours and expenses as well as external attorney and claims consultant costs (specifically including for Subcontractor and Agent For Contractor claims) incurred by Contractor while performing the Reimbursable Work as provided for in Section 23.1.4 of the Agreement, but excluding attorney hours and expenses attendant to any dispute between Owner and Contractor/Guarantor arising under the Agreement or the Contractor Guarantee;

 

5


 

Execution Version

 

  (bb)

costs to provide the Performance and Payment Bonds to Owner required under Section 9.2.1 of the Agreement;

 

  (cc)

costs incurred by Contractor for Permitted Liens;

 

  (dd)

uninsured losses and deductibles described in the Agreement; and

 

  (ee)

costs associated with Subcontractor and Agent For Contractor change orders and claims including all settlement amounts, as provided for in Section 23.1.4 of the Agreement, to the extent not addressed in clause (aa).

Notes:

1. If there is no applicable rate contained in Exhibit C to the Agreement for any item, then a new rate shall be agreed by pro-rating, extrapolating or interpolating from rates for similar work contained within Exhibit C to the Agreement. Should there be no similar items, a new rate shall be calculated from analysis agreed between Owner and Contractor based on similar labor productivity to that in the rates in Exhibit C to the Agreement. The Contractor shall provide sufficient detail to demonstrate that the labor productivity used for new rates is compatible with those used in the Agreement. Once agreed, the new rates shall remain valid for the duration of one year and be adjusted yearly thereafter in accordance with Exhibit C.

2. In the event Contractor incurs a Direct Cost in a currency other than Dollars, Contractor shall convert the amount of such Direct Cost to Dollars using the official rate of foreign exchange between such currency and the Dollar published by the central bank or comparable national monetary authority of the jurisdiction to which such other currency relates on the Business Day immediately preceding the day on which such Direct Cost is invoiced to Owner in a Request for Payment. Contractor shall include details of the calculation of such rate of foreign exchange together with the relevant Request for Payment. In no event shall Owner be responsible for Contractor’s foreign exchange hedging costs or other currency hedges except to the extent approved in accordance with clause (j) above.

 

2.

Non-Reimbursable Costs.

Non-Reimbursable Costs include costs or expenses incurred by Contractor related to the following items:

 

  (a)

Taxes based on or related to the net income, capital or net worth of Contractor or any Subcontractor;

 

6


 

Execution Version

 

  (b)

costs and expenses incurred in connection with corporate training recruiting and corporate meetings not directly related to the Work, or public and/or business relations not directly related to the Work;

 

  (c)

Liquidated damages required to be paid under the Agreement;

 

  (d)

Amounts required to be paid under Section 5.1.2, Section 30.1.2 or Section 40.4.2 of the Agreement;

 

  (e)

Any costs, expenses or other items included in Contractor’s G&A as listed in Section 3 below;

 

  (f)

Any additional general and administrative expenses, fees or mark-up of a Contractor Affiliate;

 

  (g)

Sales and use taxes on construction equipment and Contractor’s machinery, materials and other equipment to the extent not constituting a Direct Cost;

 

  (h)

Owner Costs and Direct Costs for Indemnified Liens;

 

  (i)

Owner Costs and Direct Costs to discharge and settle Subcontractor and Agent For Contractor claims arising from and solely attributable to the Gross Negligence or Willful Misconduct of Senior Supervisory Personnel;

 

  (j)

Costs, fees and expenses incurred by Contractor or required to be paid to Owner to the extent of Contractor’s obligations under Sections 30.1.1, 30.1.2 and 30.1.3 of the Agreement;

 

  (k)

Amounts required to be paid by Contractor under Section 31.3 of the Agreement, it being understood that such amounts shall not be treated as a Non-Reimbursable Cost for the purposes of Section 21.1(e) of the Agreement;

 

  (l)

incidental, indirect, punitive or consequential damages or for loss of profit, product, revenue, contract or use to the extent waived by Owner pursuant to Section 21.2 of the Agreement;

 

  (m)

Corrective Work performed during any Warranty Period in respect of which Substantial Completion was achieved prior to termination;

 

  (n)

costs and expenses of any work outside the Scope of Work described in Exhibit A of the Agreement that was performed by Contractor prior to its having received an executed Change Order or authorization from Owner;

 

  (o)

costs and expenses of performing that portion of the Work that Contractor knows to be a violation to any Laws or Permits;

 

7


 

Execution Version

 

  (p)

Contractor’s repayment to Owner of amounts previously paid by Owner under this Agreement that were determined to be a Non-Reimbursable Cost;

 

  (q)

costs and expenses incurred by Contractor in connection with Section 30.1.1 of the Agreement;

 

  (r)

costs of attorney hours and expenses attendant to any dispute between Owner and Contractor/Guarantor arising under the Agreement or the Contractor Guarantee;

 

  (s)

the amount of any arbitral award rendered in favor of Owner under Section 36.1.3 of the Agreement and the costs of such arbitration to the extent it is determined by the tribunal that Contractor should be responsible for such costs; it being understood that such amounts shall not be treated as a Non-Reimbursable Cost for the purposes of Section 21.1(e) of the Agreement;

 

  (t)

Contractor’s capital or financing costs, including principal or interest on capital used for performance of the Work;

 

  (u)

Amounts that Contractor is obligated to reimburse to Owner specified within the Agreement;

 

  (v)

charitable contributions, unless approved in advance by Owner;

 

  (w)

Contractor’s costs incurred to achieve the “make good” obligations under Section 15.3.4 of the Agreement, except as provided in Section 15.3.4 of the Agreement;

 

  (x)

any cost or expense described in Section 1 that (1) is not auditable and verifiable by Contractor’s accounts and records or (2) was improperly incurred without Owner’s approval where required;

 

  (y)

any cost or expense paid to a Subcontractor that was not due and owing to such Subcontractor in accordance with the express terms of the relevant Subcontract or this Agreement; and

 

  (z)

per-occurrence costs or expenses exceeding one thousand Dollars ($1000) incurred by Contractor or any Subcontractor for dinners, lunches, social events or team building event, to the exent not approved by Owner.

 

3.

Contractor’s G&A

A multiplier of (i) [***] for all Direct Costs (other than Tax Costs) and (ii) [***] for all Tax Costs (each, a “G&A Multiplier”) will be applied across all such Direct Costs for G&A recovery. The applicable G&A Multiplier will recover the following applicable overhead costs:

 

  a)

Home Office Executive Management

 

  b)

Corporate Equipment Administration

 

8


 

Execution Version

 

  c)

Marketing

 

  d)

Corporate Accounting/Financial Reporting/Financial Analysis

 

  e)

Corporate Risk Management Staff

 

  f)

Human Resources (excluding Facility assigned Human Resources staff)

 

  g)

Corporate Tax Staff (unless addressing Owner tax benefits)

 

  h)

Corporate I/T Staff and I/T Infrastructure

 

  i)

Corporate Treasury/Cash Management

 

  j)

Internal Audit

 

  k)

Corporate Training and Corporate Events

 

  l)

Division and District Managers

 

  m)

Corporate Legal Staff (non Facility-specific)

 

  n)

Employee Benefit Administration

 

  o)

Corporate offices and Corporate vehicles

 

  p)

Corporate telecommunications and computer hardware

 

  q)

Corporate Software and licenses

In no event shall the G&A Multiplier apply to any general and administrative expenses, fees or mark-up of a Contractor Affiliate.

 

9


 

Execution Version

EXHIBIT B-2

TARGET PRICE COMPONENTS

 

Direct Costs:

     $ [***]  

Agent For Contracts Costs:

     $ [***]  

Contractor’s G&A:

     $ [***]  

Contractor’s Margin:

     $ [***]  
  

 

 

 

Target Price:

     $ [***]  

 

1


 

Execution Version

EXHIBIT B-3

COVER COSTS EXAMPLES

[Omitted]

 

1


 

Execution Version

EXHIBIT B-4

PAYMENT PROCEDURES

[Omitted]

 

1


 

Attachment C-1

HOUSTON OPERATING CENTER

[Omitted]


 

Attachment C-2

MODULE YARD STAFF

[Omitted]


 

Attachment C-3

SITE STAFF RATES

[Omitted]


 

Attachment C-4

INDICATIVE CONSTRUCTION EQUIPMENT RENTAL RATES

[Omitted]


 

Attachment C-5

CRAFT LABOR RATES

[Omitted]


 

Attachment C-6

Other Direct Costs

[Omitted]


 

Execution Version

EXHIBIT D

SCHEDULE MILESTONES

[Omitted]

 

1


 

Execution Version

EXHIBIT E

PROJECT SCHEDULE

[Omitted]

 

1


 

Execution Version

EXHIBIT F-1

FORM OF CONTRACTOR CERTIFICATE FOR PARTIAL WAIVER OF LIENS

[Omitted]


 

EXHIBIT F-2

FORM OF SUBCONTRACTOR CERTIFICATE FOR PARTIAL WAIVER OF LIENS

[Omitted]


 

EXHIBIT F-3

FORM OF CONTRACTOR CERTIFICATE FOR FINAL WAIVER OF LIENS

[Omitted]


 

EXHIBIT F-4

FORM OF SUBCONTRACTOR CERTIFICATE FOR FINAL WAIVER OF LIENS

[Omitted]


 

EXHIBIT F-5

FORM OF CONSENT AND AGREEMENT

[Omitted]


 

EXHIBIT F-6A

FORM OF CONTRACTOR GUARANTEE (KBR)

[Omitted]


 

EXHIBIT F-6B

FORM OF CONTRACTOR GUARANTEE (ZACHRY)

[Omitted]


 

EXHIBIT F-7

FORM OF REQUEST FOR PAYMENT

[Omitted]


 

EXHIBIT F-8

FORM OF LIMITED NOTICE TO PROCEED

[Omitted]


 

EXHIBIT F-9A

PERFORMANCE BOND

[Omitted]


 

EXHIBIT F-9B

FORM OF PAYMENT BOND

[Omitted]


 

EXHIBIT F-10

FORM OF CHANGE ORDER

[Omitted]


 

EXHIBIT F-11

FORM OF LNG PRODUCTION SYSTEM

MECHANICAL COMPLETION CERTIFICATE

[Omitted]


 

EXHIBIT F-12

FORM OF LNG PRODUCTION SYSTEM RFSU CERTIFICATE

[Omitted]


 

EXHIBIT F-13

FORM OF NOTICE TO PROCEED

[Omitted]


 

EXHIBIT F-14

FORM OF TITLE INSURANCE INDEMNITY AGREEMENT

[Omitted]


 

EXHIBIT F-15

FORM OF PAYMENT STATUS AFFIDAVIT

[Omitted]


 

EXHIBIT F-16

FORM OF SUBCONTRACTOR’S PAYMENT STATUS AFFIDAVIT

[Omitted]


 

EXHIBIT F-17

FORM OF CERTIFICATE OF ACHIEVEMENT

[Omitted]


 

EXHIBIT F-18

FORM OF CERTIFICATE OF SCHEDULE MILESTONE ACHIEVEMENT

[Omitted]


 

Execution Version

EXHIBIT G

TRAINING REQUIREMENTS

[Omitted]


 

Execution Version

EXHIBIT H

SCHEDULE OF MAJOR VENDORS

[Omitted]

 

1


 

Execution Version

EXHIBIT I

PROGRESS REPORTING AND PROJECT MEETINGS

[Omitted]


 

Execution Version

EXHIBIT J

DOCUMENT CONTROL AND INFORMATION MANAGEMENT

[Omitted]

 

1


 

Execution Version

EXHIBIT K

LIST OF CONTRACTOR’S KEY PERSONNEL

[Omitted]


 

Execution Version

EXHIBIT L

PERMITS, LICENSES AND GOVERNMENT APPROVALS

[Omitted]

 

1


 

Execution Version

EXHIBIT M

RELIED UPON INFORMATION

[Omitted]

 

1


 

EXHIBIT N

OWNER SUPPLIED INFORMATION

[Omitted]


 

Execution Version

EXHIBIT O

SCHEDULE OF MAJOR SUBCONTRACTORS

[Omitted]

 

1


 

Execution Version

EXHIBIT P

MECHANICAL COMPLETION, COMMISSIONING, START-UP AND

SUBSTANTIAL COMPLETION

[Omitted]

 

1


 

Execution Version

EXHIBIT Q

OWNER PERSONNEL

[Omitted]


 

Execution Version

EXHIBIT R

DEMONSTRATION TESTS AND PERFORMANCE TESTS

[Omitted]


 

Execution Version

EXHIBIT S

LNG PRODUCTION SYSTEM HANDOVER PACKAGES

[Omitted]

 

1


 

Execution Version

EXHIBIT T

REQUIREMENTS FOR SIMULTANEOUS OPERATIONS

[Omitted]

 

1


 

Execution Version

EXHIBIT U

HEALTH, SAFETY, SECURITY AND ENVIRONMENTAL REQUIREMENTS

[Omitted]

 

1


 

Execution Version

EXHIBIT V

FIRST FILLS AND CATALYSTS

[Omitted]

 

1


 

Execution Version

EXHIBIT Y

COORDINATION PROCEDURE

[Omitted]

 

1

Exhibit 10.18

FORM OF CONTRACTOR GUARANTEE (KBR)

This GUARANTY, dated as of January 10, 2023 (this “Guaranty”), is made by KBR, INC., a Delaware corporation (“Guarantor”), for the benefit of VENTURE GLOBAL PLAQUEMINES LNG, LLC, a Delaware limited liability company (the “Beneficiary”). The Guarantor and Beneficiary are referred to herein individually as a “Party” and collectively as the “Parties”.

RECITALS

WHEREAS, the execution and delivery of this Guaranty is required pursuant to section 9.3 of that certain Engineering, Procurement and Construction Agreement (as may be amended, modified or supplemented from time to time, the “Agreement”), dated as of the date hereof, by and between KZJV LLC, a Texas limited liability company (“Obligor”) and Beneficiary;

WHEREAS, this Guaranty is entered into by the Guarantor as an inducement for Beneficiary to enter into and consummate the transactions contemplated by the Agreement; and

WHEREAS, Guarantor will derive substantial benefit from the consummation of the transactions contemplated by the Agreement.

NOW, THEREFORE, in consideration of the mutual covenants contained herein and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Guarantor and Beneficiary agree as follows:

ARTICLE 1

DEFINITIONS AND CONSTRUCTION

1.1 Definitions. All capitalized terms used but not defined herein shall have the meanings set forth for such terms in the Agreement.

ARTICLE 2

GUARANTY

2.1 Guaranty. Guarantor hereby irrevocably, absolutely, fully and unconditionally guarantees to Beneficiary and its successors and assigns the timely and complete payment and performance when and as due (whether at the stated due date, by acceleration or otherwise) of all obligations of Obligor arising under the Agreement (the “Guaranteed Obligations”), subject to the limitations and rights of Obligor set forth in the Agreement.

2.2 No Release or Discharge. This Guaranty is a direct and primary obligation of Guarantor and shall be an irrevocable, unconditional, absolute and continuing guaranty, irrespective of the following potential defenses:


2.2.1 any invalidity, voidability or unenforceability of, or defect or deficiency applicable to Obligor in respect of, the Agreement or any other documents executed in connection with the Agreement based on Obligor’s lack of corporate power and authority to enter into the Agreement or such other documents or the failure of the Agreement or such other documents to be duly authorized and executed by Obligor and its signatories;

2.2.2 any postponement or extension of the date on which any payment must be made pursuant to the Agreement or postponement or extension of the date on which any act must be performed by Obligor thereunder, provided that any such postponement or extension shall be deemed to apply to the Guarantor’s obligations hereunder in the same way that it applies to Obligor’s obligations under the Agreement;

2.2.3 whether or not Guarantor received direct notice of or consented to any modification, amendment, supplement, renewal or waiver of the Agreement or any of the terms or conditions of the Agreement, including under a Change Order, provided that the Guaranteed Obligations shall not be greater than the obligations of Obligor under the Agreement, as the Agreement may be so modified, amended, supplemented, renewed or waived without Guarantor’s consent;

2.2.4 any failure, omission or delay on the part of Beneficiary or any other Person to confirm or comply with any of the terms or conditions of the Agreement or any other documents executed in connection with the Agreement;

2.2.5 except as to applicable statutes of limitation or other contractual period of limitation, the failure, omission, delay, or refusal by Beneficiary to exercise against Obligor, in whole or in part, any right or remedy held by Beneficiary with respect to the Agreement;

2.2.6 any legal disability of Guarantor, or any release or discharge of Guarantor by a bankruptcy court;

2.2.7 any stay applicable to any enforcement of the Guaranteed Obligations against Obligor;

2.2.8 any rights of subrogation, reimbursement, indemnity or contribution that Guarantor or Beneficiary may have against Obligor;

2.2.9 any lack of knowledge by Guarantor as to the condition (including financial) of Obligor, since Guarantor shall be responsible for obtaining its own knowledge of such condition;

2.2.10 any election of remedies by Beneficiary, even if such election of remedies impairs or destroys Guarantor’s right of subrogation against Obligor;

2.2.11 any merger, consolidation, termination of or change in corporate existence, structure or ownership of Obligor, any JV Member or Guarantor, or any insolvency, bankruptcy, reorganization or other similar proceeding affecting Obligor, and JV Member or its assets;

 

2


2.2.12 any amendment, termination or material breach of, or any dispute, claim, litigation or arbitration arising under, the JV Agreement; or

2.2.13 subject to the defenses available to Guarantor pursuant to Section

2.6.2, any other occurrence or circumstance which might otherwise constitute a legal or equitable discharge or defense of a guarantor or which might otherwise limit recourse against Guarantor all without notice to or further assent by Guarantor, who shall remain bound by this Guaranty, which shall remain in full force and effect until all of the Guaranteed Obligations have been paid in full or otherwise extinguished.

No action which Beneficiary shall take or fail to take in connection with the Guaranteed Obligations, nor any course of dealing with Obligor or any other person, shall release Guarantor’s obligations hereunder, affect this Guaranty in any way, or afford Guarantor any recourse against Beneficiary. This Guaranty is in no way conditioned or contingent upon any attempt to collect from or enforce performance or payment by Obligor or upon any other event, contingency or circumstance whatsoever. Beneficiary shall not be obligated to take any action, obtain any judgment or file any claim prior to enforcing this Guarantee. Beneficiary shall not be obligated to file any claim relating to the Obligations in the event that Obligor becomes subject to a bankruptcy, reorganization or similar proceeding, and the failure of Beneficiary to so file shall not affect Guarantor’s obligations hereunder.

This Guaranty shall continue to be effective or be reinstated, as the case may be, if at any time any payment of any of the Guaranteed Obligations are annulled, set aside, invalidated, declared to be fraudulent or preferential, rescinded or must otherwise be returned, refunded or repaid by Beneficiary upon the insolvency, bankruptcy, dissolution, liquidation or reorganization of Obligor or any other guarantor, or upon or as a result of the appointment of a receiver or conservator of, or trustee for Obligor or any other guarantor or any substantial part of its property or otherwise, all as though such payment or payments had not been made.

2.3 Waiver of Rights. Subject to the limitations expressly set forth in this Guaranty, Guarantor understands and agrees that the guaranty contained in Section 2.1 shall be a continuing guaranty. Guarantor hereby expressly waives:

2.3.1 notice of acceptance of this Guaranty, of the creation or existence of any of the Guaranteed Obligations, of any of the matters described in Section 2.2 and of any action by Beneficiary in reliance hereon or in connection herewith;

2.3.2 notice of the entry into the Agreement between Obligor and Beneficiary and of any amendments, supplements or modifications thereto; or any waiver of consent under the Agreement, including waivers of the payment and performance of the obligations thereunder;

 

3


2.3.3 notice of any increase, reduction or rearrangement of Obligor’s obligations under the Agreement or any extension of time for the payment of any sums due and payable to Beneficiary under the Agreement;

2.3.4 presentment, demand for payment, notice of acceptance, notice of dishonor or nonpayment, protest and notice of protest or any other notice with respect to the Guaranteed Obligations; and

2.3.5 any requirement that suit be brought against, or any other remedy or action by Beneficiary be taken against, or any notice of default or other notice be given to, or any demand be made on Obligor or any other person, or that any other action be taken or not taken as a condition to Guarantor’s liability for the Guaranteed Obligations under this Guaranty or as a condition to the enforcement of this Guaranty against Guarantor.

2.4 No Subrogation. Guarantor will not exercise and irrevocably agrees to waive any rights against Obligor which it may acquire by way of subrogation, reimbursement, exoneration, contribution or indemnification in connection with this Guarantee by any payment made hereunder or otherwise, until all Guaranteed Obligations shall have been fully and indefeasibly paid and performed. If (a) Guarantor makes payment to Beneficiary of all or any part of the Guaranteed Obligations and (b) all of the then outstanding Guaranteed Obligations shall have been paid in full, Beneficiary shall, at Guarantor’s request, execute and deliver to Guarantor documents to evidence the transfer by subrogation to Guarantor of any interest in the Guaranteed Obligations resulting from such payment by Guarantor. If any amount shall be paid to Guarantor on account of such subrogation, contribution, reimbursement or indemnity rights at any time when all of the Guaranteed Obligations and all amounts owing hereunder shall not have been performed and paid in full, such amount shall be held by Guarantor in trust for Beneficiary, segregated from other funds of Guarantor, and shall, forthwith upon receipt by Guarantor, be turned over to Beneficiary in the exact form received by Guarantor (duly endorsed by Guarantor to Beneficiary, if required), to be applied against the Guaranteed Obligations, whether or not matured, in such order as Beneficiary may determine.

2.5 Demand and Payment. Beneficiary may provide written notice to Guarantor pursuant to Section 5.1 at any time if Obligor fails to punctually pay or perform any of the Guaranteed Obligations. There are no other requirements of notice, presentment or demand. Guarantor shall pay, or cause to be paid, such Guaranteed Obligations within five (5) Business Days of receipt of such notice, unless, within such period, the default giving rise to such notice has been remedied. If Beneficiary is prevented from making a demand on Guarantor as a result of any applicable Law, any injunction, order or other action of any court or other Government Authority or any stay, moratorium or other action in any bankruptcy, insolvency or other similar proceeding, Guarantor shall not be excused from paying and performing its obligations under this Guaranty as and when due. All payments by Guarantor hereunder shall be paid without setoff or deduction in U.S. dollars in immediately available funds to such accounts as may be designated by Beneficiary from time to time. Guarantor agrees to pay on demand all fees and out of pocket expenses (including the reasonable fees and expenses of Beneficiary’s counsel) in any way relating to the enforcement or protection of the rights of Beneficiary hereunder. Any amount due and payable hereunder shall, if not paid when due, accrue interest at the Late Payment Rate from the date such payment was due until the date such payment is made in full.

 

4


2.6 Primary Liability of Guarantor; Guarantor’s Defenses.

2.6.1 Guarantor agrees that Beneficiary may enforce this Guaranty without the necessity at any time of resorting to or exhausting any other security or collateral, including any other Contractor Guarantee provided by any other Contractor Guarantor, or exercising or exhausting any other remedies against Obligor or any other Contractor Guarantor. This is a guaranty of payment and performance when and as due and not merely of collection.

2.6.2 Notwithstanding anything to the contrary stated herein or in the Agreement or any documents related thereto, Guarantor’s undertakings and obligations hereunder with respect to the Agreement are derivative of and not in excess of Obligor’s obligations under the Agreement and Guarantor may assert as a defense, right of set-off or counterclaim to its obligations hereunder any defense, right of set-off or counterclaim that Obligor may have to such Guaranteed Obligations under the Agreement or otherwise, even if Obligor fails to raise the same, except (i) a defense based on the discharge of the Guaranteed Obligations as to Obligor in a bankruptcy or insolvency proceeding or (ii) other defenses expressly waived hereunder.

2.7 Continuing Guaranty. Guarantor’s obligations under Section 2.1 of this Guaranty shall continue in force and effect until the Guaranteed Obligations have been fully performed or otherwise extinguished under the Agreement, at which time this Guaranty and all of Guarantor’s obligations hereunder shall terminate and expire. Guarantor agrees that any judgment between Obligor and Beneficiary under the Agreement (whether in contested litigation or arbitration or otherwise) shall be conclusive and binding on Guarantor for the purposes of determining Guarantor’s obligations under this Guaranty.

ARTICLE 3

REPRESENTATIONS AND WARRANTIES

3.1 Representations and Warranties of Guarantor. Guarantor represents and warrants as follows:

3.1.1 It is a corporation, duly formed, validly existing and in good standing under the laws of the State of Delaware.

3.1.2 It has all requisite power and authority to execute and deliver this Guaranty and to perform all obligations to be performed by it hereunder. The execution and delivery of this Guaranty and the consummation of the transactions contemplated hereby have been duly and validly authorized and approved by all requisite corporate action on its part. This Guaranty has been duly and validly executed and delivered by it and this Guaranty constitutes a valid and binding obligation of it, enforceable against it in accordance with its terms.

 

5


3.1.3 The execution and delivery of this Guaranty by it and the performance of its obligations hereunder by it do not and shall not: (i) violate any applicable Law or require any filing with, consent, approval or authorization of, or notice to, any Government Authority or any other Person, except as otherwise obtained prior to the date hereof, (ii) violate any of its organizational documents or (iii) breach or conflict with any material contract to which it is a party or by which it may be bound, result in the termination of any such material contract, result in the creation of any lien upon any of its assets or constitute an event which, after notice or lapse of time or both, would result in any such breach, termination or creation of a lien upon any of its assets.

ARTICLE 4

COVENANTS

4.1 Guarantor Financial Statements. As soon as available, but in any event within sixty (60) Days after the end of the first three fiscal quarters of the Guarantor, Guarantor shall make available to Obligor for delivery to Beneficiary the unaudited and consolidated balance sheet of the Guarantor, as of the end of such quarter, the related consolidated statements of income, cash flows, and retained earnings and stockholders’ equity for such quarter, all of which shall be certified by the chief financial officer or equivalent officer of the Guarantor subject to normal year-end audit adjustments. As soon as available, but in any event no later than one-hundred twenty (120) Days after the end of each fiscal year of the Guarantor, Guarantor shall deliver to Beneficiary a copy of the audited consolidated balance sheets at the end of each such year as well as the related consolidated statements of income, retained earnings, and cash flows for such year.

4.2 Joint Venture. Guarantor shall not, and shall cause the JV Member with whom it is Affiliated not to, in each case without the prior written consent of Beneficiary:

4.2.1 amend or modify the JV Agreement in a manner that would cause the representation of Obligor set forth in section 28.2.9 of the Agreement, if repeated as of such time, to be materially inaccurate or misleading in any respect;

4.2.2 assign, sell, transfer, encumber (other than under the JV Agreement) or convey its ownership interests in Obligor to any Person other than its wholly-owned Affiliate or the other JV Member in accordance with the JV Agreement;

4.2.3 amend or modify the division of responsibilities between the JV Members in the JV Agreement in a manner that would be materially inconsistent with the division of responsibilities set forth in exhibit A to the Agreement;

4.2.4 amend, modify or waive any of its “step-in” rights under the JV Agreement; or

4.2.5 permit Obligor to engage in any business other than the performance of the Agreement and such other activities as are incidental thereto.

 

6


4.3 Maintenance of Existence. Guarantor shall, and shall cause the JV Member with whom it is Affiliated to, cause Obligor to preserve, renew and keep in full force and effect its organizational existence and good standing in its jurisdiction of formation and maintain and renew all of the powers, licenses, rights, privileges and franchises necessary for its performance of the Agreement and in the normal conduct of its business. Guarantor shall not, and shall cause JV Member with whom it is Affiliated not to, seek or voluntarily consummate any liquidation, bankruptcy, dissolution or reorganization of Obligor.

4.4 Notice of Disputes. Guarantor shall provide prompt written notice to Beneficiary of any material dispute, claim, litigation, arbitration or other proceeding arising under the JV Agreement.

4.5 No Restriction. Neither Guarantor nor any of its Affiliates shall agree or become subject to any restriction, contractual or otherwise, that would prohibit it or any of its Affiliates from bidding for or entering into a contract or guarantee, as applicable, in respect of the second ten (10) MTPA (nameplate) phase of the Plaquemines LNG export project under development by Beneficiary and its Affiliates, unless Beneficiary’s prior written approval of such restriction is obtained.

ARTICLE 5

MISCELLANEOUS

5.1 Notices. All notices and other communications required or permitted to be given by any provision of this Guaranty shall be in writing and mailed (certified or registered mail, postage prepaid, return receipt requested) or sent by hand or overnight courier, or by facsimile transmission (with acknowledgment received), charges prepaid and addressed to the intended recipient as follows, or to such other addresses or numbers as may be specified by a Party from time to time by like notice to the other Parties:

If to Guarantor, at:

If to Beneficiary, at:

 

7


All notices and other communications given in accordance with the provisions of this Guaranty shall be deemed to have been given and received: (i} when delivered, if delivered by hand or transmitted by facsimile (with acknowledgment received); (ii) five (5) Business Days after the same are sent by certified or registered mail, postage prepaid, return receipt requested; or (iii) one (I) Business Day after the same arc sent by a reliable overnight courier service, with acknowledgment of receipt.

5.2 Assignment. This Guaranty shall be binding upon and inure to the benefit of the Parties and their respective successors and permitted assigns. Neither Party may assign (by contract, stock sale, operation of law or otherwise) either this Guaranty or any of its rights, interests, or obligations hereunder without the express prior written consent of the other Party, and any attempted assignment, without such consent, shall be null and void; provided, however that Beneficiary may assign this Agreement, without the consent of Guarantor (but with written notice to Guarantor) in connection with (i) an assignment of the Agreement by Beneficiary permitted under the Agreement or (ii) a collateral assignment of this Guaranty by Beneficiary to any Lender.

5.3 Rights of Third Parties. Nothing expressed or implied in this Guaranty is intended or shall be construed to confer upon or give any Person, other than Beneficiary, any right or remedies under or by reason of this Guaranty.

5.4 Entire Agreement. This Guaranty constitutes the entire agreement between the Parties with respect to the subject matter hereof and supersedes any prior understandings, negotiations, agreements, or representations between the Parties of any nature, whether written or oral, to the extent they relate in any way to the subject matter hereof.

5.5 Counterparts. This Guaranty may be executed in any number of counterparts, each of which shall be deemed an original but all of which together will constitute one and the same instrument.

5.6 Amendments. This Guaranty may be amended or modified in whole or in part, and terms and conditions may be waived, only by a duly authorized agreement executed by Guarantor and Beneficiary which makes reference to this Guaranty.

5.7 Severability. If any provision of this Guaranty or the application of any such provision to any Person or circumstance shall be declared by any court of competent jurisdiction to be invalid, illegal, void or unenforceable in any respect, all other provisions of this Guaranty, or the application of such provision to Persons or circumstances other than those as to which it has been held invalid, illegal, void or unenforceable, shall nevertheless remain in full force and effect and will in no way be affected, impaired or invalidated thereby. Upon such determination that any provision, or the application of any such provision, is invalid, illegal, void or unenforceable, the parties shall negotiate in good faith to modify this Guaranty so as to effect the original intent of the parties as closely as possible to the fullest extent permitted by applicable Law in an acceptable manner to the end that the transactions contemplated hereby are fulfilled to the greatest extent possible.

 

8


5.8 Financing. Guarantor acknowledges that Beneficiary intends to obtain financing, and Guarantor agrees to cooperate with Beneficiary and the Lenders in connection with such financing, including, but not limited to, entering into a Consent and Agreement with the Lenders, in a form substantially similar to Exhibit F-5 to the Agreement.

5.9 Governing Law; Jurisdiction.

5.9.1 This Guaranty and all claims arising out of or relating to this Guaranty and the transactions contemplated hereby shall be governed by the laws of the State of New York, without regard to the conflicts of law principles that would result in the application of the laws of any other jurisdiction.

5.9.2 Each Party (a) irrevocably submits to the exclusive jurisdiction of any federal court or state court sitting in the Southern District of New York in any dispute, claim or controversy arising under or relating to this Guaranty, (b) agrees that all claims in such action may be decided in such court, (c) waives, to the fullest extent it may effectively do so, the defense of inconvenient forum and (d) consents to the service of process by mail in accordance with the notice provisions of this Guaranty.

5.9.3 Each Party waives all right to trial by jury in any action or proceeding to enforce or defend any rights under this Guaranty and any document executed in connection herewith.

[signature page follows]

 

9


IN WITNESS WHEREOF, this Guaranty has been duly executed and delivered by Guarantor as of the date first above written.

 

GUARANTOR
KBR, Inc.
By:  

/s/ Mark W. Sopp

Name:   Mark W. Sopp
Title:   EVP/CFO
BENEFICIARY
VENTURE GLOBAL PLAQUEMINES LNG, LLC
By:  

/s/ Keith Larson

Name:   Keith Larson
Title:   Secretary

[Signature Page - Guarantee]

 

10

Exhibit 10.19

FORM OF CONTRACTOR GUARANTEE (ZACHRY)

This GUARANTY, dated as of January 10, 2023 (this “Guaranty”), is made by ZACI IRY HOLDINGS, INC., a Delaware corporation (“Guarantor’’), for the benefit of VENTURE GLOBAL Plaquemines LNG, LLC, a Delaware limited liability company (the ‘‘Beneficiary”). The Guarantor and Beneficiary arc referred to herein individually as a “Party” and collectively as the ‘‘Parties”.

RECITALS

WHEREAS, the execution and delivery of this Guaranty is required pursuant to section 9.3 of that certain Engineering, Procurement and Construction Agreement (as may be amended, modified or supplemented from time to time, the “Agreement”), dated as of the date hereof, by and between KZ.IV LLC. a Texas limited liability company (“Obligor”) and Beneficiary;

WIIERFAS, this Guaranty is entered into by the Guarantor as an inducement for Beneficiary to enter into and consummate the transactions contemplated by the Agreement; and

WHEREAS, Guarantor will derive substantial benefit from the consummation of the transactions contemplated by the Agreement.

NOW, THEREFORE, in consideration of the mutual covenants contained herein and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Guarantor and Beneficiary agree as follows:

ARTICLE 1

DEFINITIONS AND CONSTRUCTION

1.1 Definitions. All capitalized terms used but not defined herein shall have the meanings set forth for such terms in the Agreement.

ARTICLE 2

GUARANTY

2.1 Guaranty. Guarantor hereby irrevocably, absolutely, fully and unconditionally guarantees to Beneficiary and its successors and assigns the timely and complete payment and performance when and as due (whether at the stated due date, by acceleration or otherwise) of all obligations of Obligor arising under the Agreement (the “Guaranteed Obligations”), subject to the limitations and rights of Obligor set forth in the Agreement.


2.2 No Release or Discharge. This Guaranty is a direct and primary obligation of Guarantor and shall be an irrevocable, unconditional, absolute and continuing guaranty, irrespective of the following potential defenses:

2.2.1 any invalidity, voidability or unenforceability of, or defect or deficiency applicable to Obligor in respect of: the Agreement or any other documents executed in connection with the Agreement based on Obligor’s lack of corporate power and authority to enter into the Agreement or such other documents or the failure of the Agreement or such other documents to be duly authorized and executed by Obligor and its signatories;

2.2.2 any postponement or extension of the date on which any payment must be made pursuant to the Agreement or postponement or extension of the date on which any act must be performed by Obligor thereunder, provided that any such postponement or extension shall be deemed to apply to the Guarantor’s obligations hereunder in the same way that it applies to Obligor’s obligations under the Agreement;

2.2.3 whether or not Guarantor received direct notice of or consented to any modification, amendment, supplement, renewal or waiver of the Agreement or any of the terms or conditions of the Agreement, including under a Change Order, provided that the Guaranteed Obligations shall not be greater than the obligations of Obligor under the Agreement, as the Agreement may be so modified, amended, supplemented, renewed or waived without Guarantor’s consent;

2.2.4 any failure, omission or delay on the part of Beneficiary or any other Person to confirm or comply with any of the terms or conditions of the Agreement or any other documents executed in connection with the Agreement;

2.2.5 except as to applicable statutes of limitation or other contractual period of limitation, the failure, omission, delay, or refusal by Beneficiary to exercise against Obligor, in whole or in part, any right or remedy held by Beneficiary with respect to the Agreement;

2.2.6 any legal disability of Guarantor, or any release or discharge of Guarantor by a bankruptcy court;

2.2.7 any stay applicable to any enforcement of the Guaranteed Obligations against Obligor;

2.2.8 any rights of subrogation, reimbursement, indemnity or contribution that Guarantor or Beneficiary may have against Obligor;

2.2.9 any lack of knowledge by Guarantor as to the condition (including financial) of Obligor, since Guarantor shall be responsible for obtaining its own knowledge of such condition;

 

35


2.2.10 any election of remedies by Beneficiary, even if such election of remedies impairs or destroys Guarantor’s right of subrogation against Obligor;

2.2.11 any merger, consolidation, termination of or change in corporate existence, structure or ownership of Obligor, any JV Member or Guarantor, or any insolvency, bankruptcy, reorganization or other similar proceeding affecting Obligor, and JV Member or its assets;

2.2.12 any amendment, termination or material breach of, or any dispute, claim, litigation or arbitration arising under, the JV Agreement; or

2.2.13 subject to the defenses available to Guarantor pursuant to Section 2.6.2, any other occurrence or circumstance which might otherwise constitute a legal or equitable discharge or defense of a guarantor or which might otherwise limit recourse against Guarantor all without notice to or further assent by Guarantor, who shall remain bound by this Guaranty, which shall remain in full force and effect until all of the Guaranteed Obligations have been paid in full or otherwise extinguished.

No action which Beneficiary shall take or fail to take in connection with the Guaranteed Obligations, nor any course of dealing with Obligor or any other person, shall release Guarantor’s obligations hereunder, affect this Guaranty in any way, or afford Guarantor any recourse against Beneficiary. This Guaranty is in no way conditioned or contingent upon any attempt to collect from or enforce performance or payment by Obligor or upon any other event, contingency or circumstance whatsoever. Beneficiary shall not be obligated to take any action, obtain any judgment or file any claim prior to enforcing this Guarantee. Beneficiary shall not be obligated to file any claim relating to the Obligations in the event that Obligor becomes subject to a bankruptcy, reorganization or similar proceeding, and the failure of Beneficiary to so file shall not affect Guarantor’s obligations hereunder,

This Guaranty shall continue to be effective or be reinstated, as the case may be, if at any time any payment of any of the Guaranteed Obligations arc annulled, set aside, invalidated, declared to be fraudulent or preferential, rescinded or must otherwise be returned, refunded or repaid by Beneficiary upon the insolvency, bankruptcy, dissolution, liquidation or reorganization of Obligor or any other guarantor, or upon or as a result of the appointment of a receiver or conservator of, or trustee for Obligor or any other guarantor or any substantial part of its property or otherwise, all as though such payment or payments had not been made.

2.3 Waiver of Rights. Subject to the limitations expressly set forth in this Guaranty, Guarantor understands and agrees that the guaranty contained in Section 2.1 shall be a continuing guaranty. Guarantor hereby expressly waives:

2.3.1 notice of acceptance of this Guaranty, of the creation or existence of any of the Guaranteed Obligations, of any of the matters described in Section 2.2 and of any action by Beneficiary in reliance hereon or in connection herewith;

2.3.2 notice of the entry into the Agreement between Obligor and Beneficiary and of any amendments, supplements or modifications thereto; or any waiver of consent under the Agreement. including waivers of the payment and performance of the obligations thereunder;

 

36


2.3.3 notice of any increase, reduction or rearrangement of Obligor’s obligations under the Agreement or any extension of time for the payment of any sums due and payable to Beneficiary under the Agreement;

2.3.4 presentment, demand for payment, notice of acceptance, notice of dishonor or nonpayment, protest and notice of protest or any other notice with respect to the Guaranteed Obligations; and

2.3.5 any requirement that suit be brought against, or any other remedy or action by Beneficiary be taken against, or any notice of default or other notice be given to, or any demand be made on Obligor or any other person, or that any other action be taken or not taken as a condition to Guarantor’s liability for the Guaranteed Obligations under this Guaranty or as a condition to the enforcement of this Guaranty against Guarantor.

2.4 No Subrogation. Guarantor will not exercise and irrevocably agrees to waive any rights against Obligor which it may acquire by way of subrogation, reimbursement, exoneration, contribution or indemnification in connection with this Guarantee by any payment made hereunder or otherwise, until all Guaranteed Obligations shall have been fully and indefeasibly paid and performed. If (a) Guarantor makes payment to Beneficiary of all or any part of the Guaranteed Obligations and (b) all of the then outstanding Guaranteed Obligations shall have been paid in full, Beneficiary shall, at Guarantor’s request, execute and deliver to Guarantor documents to evidence the transfer by subrogation to Guarantor of any interest in the Guaranteed Obligations resulting from such payment by Guarantor. If any amount shall be paid to Guarantor on account of such subrogation, contribution, reimbursement or indemnity rights at any time when all of the Guaranteed Obligations and all amounts owing hereunder shall not have been performed and paid in full, such amount shall be held by Guarantor in trust for Beneficiary, segregated from other funds of Guarantor, and shall, forthwith upon receipt by Guarantor, be turned over to Beneficiary in the exact form received by Guarantor (duly endorsed by Guarantor to Beneficiary, if required), to be applied against the Guaranteed Obligations, whether or not matured, in such order as Beneficiary may determine.

2.5 Demand and Payment. Beneficiary may provide written notice to Guarantor pursuant to Section 5.1 at any time if Obligor fails to punctually pay or perform any of the Guaranteed Obligations. There are no other requirements of notice, presentment or demand. Guarantor shall pay, or cause to be paid, such Guaranteed Obligations within five (5) Business Days of receipt of such notice, unless, within such period, the default giving rise to such notice has been remedied. If Beneficiary is prevented from making a demand on Guarantor as a result of any applicable Law, any injunction, order or other action of any court or other Government Authority or any stay, moratorium or other action in any bankruptcy, insolvency or other similar proceeding, Guarantor shall not be excused from paying and performing its obligations under this Guaranty as and when due. All payments by Guarantor hereunder shall be paid without setoff or deduction in U.S. dollars in immediately available funds to such accounts as may be designated by Beneficiary from time to time. Guarantor agrees to pay on demand all fees and out of pocket expenses

 

37


(including the reasonable fees and expenses of Beneficiary’s counsel) in any way relating to the enforcement or protection of the rights of Beneficiary hereunder. Any amount due and payable hereunder shall, if not paid when due, accrue interest at the Late Payment Rate from the date such payment was due until the date such payment is made in full.

2.6 Primary Liability of Guarantor; Guarantor’s Defenses.

2.6.1 Guarantor agrees that Beneficiary may enforce this Guaranty without the necessity at any time of resorting to or exhausting any other security or collateral, including any other Contractor Guarantee provided by any other Contractor Guarantor, or exercising or exhausting any other remedies against Obligor or any other Contractor Guarantor, This is a guaranty of payment and performance when and as due and not merely of collection.

2.6.2 Notwithstanding anything to the contrary stated herein or in the Agreement or any documents related thereto, Guarantor’s undertakings and obligations hereunder with respect to the Agreement arc derivative of and not in excess of Obligor’s obligations under the Agreement and Guarantor may assert as a defense, right of set-off or counterclaim to its obligations hereunder any defense, right of set-off or counterclaim that Obligor may have to such Guaranteed Obligations under the Agreement or otherwise, even if Obligor fails to raise the same, except (i) a defense based on the discharge of the Guaranteed Obligations as to Obligor in a bankruptcy or insolvency proceeding or (ii) other defenses expressly waived hereunder.

2.7 Continuing Guaranty. Guarantor’s obligations under Section 2.1 of this Guaranty shall continue in force and effect until the Guaranteed Obligations have been fully performed or otherwise extinguished under the Agreement, at which time this Guaranty and all of Guarantor’s obligations hereunder shall terminate and expire. Guarantor agrees that any judgment between Obligor and Beneficiary under the Agreement (whether in contested litigation or arbitration or otherwise) shall be conclusive and binding on Guarantor for the purposes of determining Guarantor’s obligations under this Guaranty.

ARTICLE 3

REPRESENTATIONS AND WARRANTIES

3.1 Representations and Warranties of Guarantor. Guarantor represents and warrants as follows:

3.1.1 It is a corporation, duly formed, validly existing and 111 good standing under the laws of the State of Delaware.

3.1.2 It has all requisite power and authority to execute and deliver this Guaranty and to perform all obligations to be performed by it hereunder. The execution and delivery of this Guaranty and the consummation of the transactions contemplated hereby have been duly and validly authorized and approved by all requisite corporate action on its part. This Guaranty has been duly and validly executed and delivered by it and this Guaranty constitutes a valid and binding obligation of it, enforceable against it in accordance with its terms.

 

38


3.1.3 The execution and delivery of this Guaranty by it and the performance of its obligations hereunder by it do not and shall not: (i) violate any applicable Law or require any filing with, consent, approval or authorization of, or notice to, any Government Authority or any other Person, except as otherwise obtained prior to the date hereof, (ii) violate any of its organizational documents or (iii) breach or conflict with any material contract to which it is a party or by which it may be bound, result in the termination of any such material contract, result in the creation of any lien upon any of its assets or constitute an event which, after notice or lapse of time or both, would result in any such breach, termination or creation of a lien upon any of its assets.

ARTICLE 4

COVENANTS

4.1 Guarantor Financial Statements. As soon as available, but in any event within sixty (60) Days after the end of the first three fiscal quarters of the Guarantor, Guarantor shall make available to Obligor for delivery to Beneficiary the unaudited and consolidated balance sheet of the Guarantor, as of the end of such quarter, the related consolidated statements of income, cash flows, and retained earnings and stockholders’ equity for such quarter, all of which shall be certified by the chief financial officer or equivalent officer of the Guarantor subject to normal year-end audit adjustments. As soon as available, but in any event no later than one-hundred twenty (120) Days after the end of each fiscal year of the Guarantor, Guarantor shall deliver to Beneficiary a copy of the audited consolidated balance sheets at the end of each such year as well as the related consolidated statements of income, retained earnings. and cash flows for such year.

4.2 Joint Venture. Guarantor shall not, and shall cause the JV Member with whom it is Affiliated not to, in each case without the prior written consent of Beneficiary:

4.2.1 amend or modify the JV Agreement in a manner that would cause the representation of Obligor set forth in section 28.2.9 of the Agreement, if repeated as of such time, to be materially inaccurate or misleading in any respect;

4.2.2 assign, sell, transfer, encumber (other than under the JV Agreement) or convey its ownership interests in Obligor to any Person other than its wholly-owned Affiliate or the other JV Member in accordance with the JV Agreement;

4.2.3 amend or modify the division of responsibilities between the JV Members in the JV Agreement in a manner that would be materially inconsistent with the division of responsibilities set forth in exhibit A to the Agreement;

4.2.4 amend, modify or waive any of its “step-in” rights under the JV Agreement; or

 

39


4.2.5 permit Obligor to engage in any business other than the performance of the Agreement and such other activities as arc incidental thereto.

4.3 Maintenance of Existence. Guarantor shall, and shall cause the JV Member with whom it is Affiliated to, cause Obligor to preserve, renew and keep in full force and effect its organizational existence and good standing in its jurisdiction of formation and maintain and renew all of the powers, licenses, rights, privileges and franchises necessary for its performance of the Agreement and in the normal conduct of its business. Guarantor shall not, and shall cause JV Member with whom it is Affiliated not to, seek or voluntarily consummate any liquidation, bankruptcy, dissolution or reorganization of Obligor.

4.4 Notice of Disputes. Guarantor shall provide prompt written notice to Beneficiary of any material dispute, claim, litigation, arbitration or other proceeding arising under the JV Agreement.

4.5 No Restriction. Neither Guarantor nor any of its Affiliates shall agree or become subject to any restriction, contractual or otherwise, that would prohibit it or any of its Affiliates from bidding for or entering into a contract or guarantee, as applicable, in respect of the second ten (10) MTPA (nameplate) phase of the Plaquemines LNG export project under development by Beneficiary and its Affiliates, unless Beneficiary’s prior written approval of such restriction is obtained.

ARTICLE 5

MISCELLANEOUS

5.1 Notices. All notices and other communications required or permitted to be given by any provision of this Guaranty shall be in writing and mailed (certified or registered mail, postage prepaid, return receipt requested) or sent by hand or overnight courier, or by facsimile transmission (with acknowledgment received), charges prepaid and addressed to the intended recipient as follows, or to such other addresses or numbers as may be specified by a Party from time to time by like notice to the other parties:

If to Guarantor, at:

If to Beneficiary, at:

 

40


All notices and other communications given in accordance with the provisions of this Guaranty shall be deemed to have been given and received: (i) when delivered, if delivered by hand or transmitted by facsimile (with acknowledgment received); (ii) five (5) Business Days after the same are sent by certified or registered mail, postage prepaid, return receipt requested; or (iii) one (1) Business Day after the same are sent by a reliable overnight courier service, with acknowledgment of receipt.

5.2 Assignment. This Guaranty shall be binding upon and inure to the benefit of the Parties and their respective successors and permitted assigns. Neither Party may assign (by contract, stock sale, operation of law or otherwise) either this Guaranty or any of its rights, interests, or obligations hereunder without the express prior written consent of the other Party, and any attempted assignment, without such consent, shall be null and void; provided, however that Beneficiary may assign this Agreement, without the consent of Guarantor (but with written notice to Guarantor) in connection with (i) an assignment of the Agreement by Beneficiary permitted under the Agreement or (ii) a collateral assignment of this Guaranty by Beneficiary to any Lender.

5.3 Rights of Third Parties. Nothing expressed or implied in this Guaranty is intended or shall be construed to confer upon or give any Person, other than Beneficiary, any right or remedies under or by reason of this Guaranty.

5.4 Entire Agreement. This Guaranty constitutes the entire agreement between the Parties with respect to the subject matter hereof and supersedes any prior understandings, negotiations, agreements, or representations between the Parties of any nature, whether written or oral, to the extent they relate in any way to the subject matter hereof.

5.5 Counterparts. This Guaranty may be executed in any number of counterparts, each of which shall be deemed an original but all of which together will constitute one and the same instrument.

5.6 Amendments. This Guaranty may be amended or modified in whole or in part, and terms and conditions may be waived, only by a duly authorized agreement executed by Guarantor and Beneficiary which makes reference to this Guaranty.

5.7 Severability. If any provision of this Guaranty or the application of any such provision to any Person or circumstance shall be declared by any court of competent jurisdiction to be invalid, illegal, void or unenforceable in any respect, all other provisions of this Guaranty, or the application of such provision to Persons or circumstances other than those as to which it has been held invalid, illegal, void or unenforceable, shall nevertheless remain in full force and effect and will in no way be affected, impaired or invalidated thereby. Upon such determination that any provision, or the application of any such provision, is invalid, illegal, void or unenforceable, the parties shall negotiate in good faith to modify this Guaranty so as to effect the original intent of the parties as closely as possible to the fullest extent permitted by applicable Law in an acceptable manner to the end that the transactions contemplated hereby are fulfilled to the greatest extent possible.

 

41


5.8 Financing. Guarantor acknowledges that Beneficiary intends to obtain financing, and Guarantor agrees to cooperate with Beneficiary and the Lenders in connection with such financing, including, but not limited to, entering into a Consent and Agreement with the Lenders, in a form substantially similar to Exhibit F-5 to the Agreement.

5.9 Governing Law; Jurisdiction.

5.9.1 This Guaranty and all claims arising out of or relating to this Guaranty and the transactions contemplated hereby shall be governed by the laws of the State of New York, without regard to the conflicts of law principles that would result in the application of the laws of any other jurisdiction.

5.9.2 Each Party (a) irrevocably submits to the exclusive jurisdiction of any federal court or state court sitting in the Southern District of New York in any dispute, claim or controversy arising under or relating to this Guaranty, (b) agrees that all claims in such action may be decided in such court, (c) waives, to the fullest extent it may effectively do so, the defense of inconvenient forum and (d) consents to the service of process by mail in accordance with the notice provisions of this Guaranty.

5.9.3 Each Party waives all right to trial by jury in any action or proceeding to enforce or defend any rights under this Guaranty and any document executed in connection herewith.

[signature page follows]

 

42


IN WITNESS WHEREOF, this Guaranty has been duly executed and delivered by Guarantor as of the date first above written.

 

GUARANTOR
ZACHRY HOLDINGS, INC.
Name:  

/s/ C. Ryan Frames

By:   C. Ryan Frames
Title:   Senior Vice President
BENEFICIARY
VENTURE GLOBAL PLAQUEMINES LNG, LLC
Name:  

/s/ Keith Larson

By:   Keith Larson
Title:   Secretary

[Signature Page - Guarantee]

Exhibit 10.20

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

AMENDMENT NO. 1 TO

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

THIS AMENDMENT NO. 1 TO ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Amendment”), entered into effective as of September 26, 2023 (the “Effective Date”), is entered into by and between VENTURE GLOBAL PLAQUEMINES LNG, LLC, a Delaware limited liability company (“Owner”), and KZJV LLC, a Texas limited liability company (“Contractor”).

W I T N E S S E T H

WHEREAS, Owner and Contractor are parties to that certain Engineering, Procurement and Construction Agreement dated as of January 10, 2023 (the “Agreement”); and

WHEREAS, the Parties are aware of the current Project Schedule progress, and Owner wishes to implement the incentive program set forth herein; and

WHEREAS, pursuant to Section 41.8 of the Agreement, the Parties desire to amend the Agreement as set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants and provisions herein contained, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby covenant and agree as follows:

1. Defined Terms. Capitalized terms not defined in this Amendment shall have the meaning given to such terms in the Agreement.

2. Amendments. Effective as of the Effective Date, the Agreement is hereby amended as follows:

(i) Article 1 of the Agreement is hereby amended to insert the following new defined terms in alphabetical order:

““Certificate of Incentive Performance Milestone Achievement” means the certificate, in substantially the form set forth as Exhibit F-19, to be provided by Contractor confirming in writing that the Incentive Performance Milestone has been achieved and explaining how it was achieved.

Eligible Personnel” means Contractor’s or its Affiliate’s personnel assigned to a eligible position identified on Exhibit AA who: (i) is engaged in the performance of the Work at the Job Site on a full-time basis for a period of at least six (6) consecutive months prior to the completion of the Incentive Performance Milestone; (ii) has an Owner-approved PAAF and remains working on the Job Site through the applicable demobilization date, as mutually agreed upon by Owner and Contractor (such agreement to demobilize shall not be unreasonably withheld by Owner); (iii) is employed in good standing (as determined by Contractor) as of the date on which the Incentive Payment is to be paid; (iv) is identified on Contractor’s performance milestone incentive list, as approved by Owner and updated by Contractor on a monthly basis and (v) is not part of part of Contractor’s commissioning staff.

 

 

1


 

Incentive Level” means, with respect to any Eligible Personnel, the numeric incentive level identified opposite such Eligible Personnel’s position on Exhibit AA.

Incentive Payment” means, with respect to any Eligible Personnel, the amount payable by Owner on the basis of such Eligible Personnel’s Incentive Level upon the completion of the Incentive Performance Milestone.

Incentive Performance Milestone” means the milestone identified as an Incentive Performance Milestone on Exhibit AA.

Incentive Performance Milestone Deadline” means, with respect to the Incentive Performance Milestone, the date identified on Exhibit AA as the incentive performance milestone deadline for the Incentive Performance Milestone.”

(ii) Article 16 of the Agreement is hereby amended by inserting the following new Section 16.4 immediately following Section 16.3:

16.4 PERFORMANCE INCENTIVE

16.4.1 In consideration for Contractor’s safe and timely completion of the Work, Owner will, subject to Section 16.4.5, pay to Contractor, not later than [***] days following the date of achievement of the Incentive Performance Milestone and Request for Payment, an amount in respect of the Incentive Performance Milestone equal to the sum of one (1) Incentive Payment for each and every Eligible Personnel; provided that Contractor has achieved the Incentive Performance Milestone on or prior to the Incentive Performance Milestone Deadline. Contractor shall not be entitled to payment in respect of the Incentive Payment unless and until the achievement of the Incentive Performance Milestone is confirmed by a Certificate of Incentive Performance Milestone Achievement to be provided by Contractor together with the relevant Request for Payment.

16.4.2 If Contractor achieves the Incentive Performance Milestone after the Incentive Performance Milestone Deadline, no Incentive Payment shall be due and payable by Owner. For the avoidance of doubt and solely for the purposes set forth herein, the Incentive Performance Milestone Deadline defined herein is not subject to adjustment for any reason, including Owner Caused Delay and Force Majeure.

 

2


 

16.4.3 Contractor shall invoice Owner for an Incentive Payment due and payable hereunder by submitting to Owner, together with the applicable Request for Payment, [***], and a certificate by an authorized representative of Contractor that certifies the invoice is in compliance with this Section 16.4. No Incentive Payment due and payable under this Agreement shall be considered a “Direct Cost” or included in the calculation of Contractor’s G&A or Contractor’s Margin, nor shall such amounts affect or modify the Target Price or the calculation of Total Costs or Total Cost Exclusions.

16.4.4 If an Eligible Personnel in respect of whom an Incentive Payment has been made by Owner ceases to be an Eligible Personnel prior to the approved maturity date for such Eligible Personnel, all Incentive Payments paid in respect of such Eligible Personnel shall be credited to Owner in Contractor’s next following Request for Payment.

16.4.5 Prior to the earlier of (a) the Incentive Performance Milestone Deadline and (b) the time that the Incentive Performance Milestone has been achieved, Owner shall be permitted, without cause and for any reason, to cancel the Incentive Payment and Incentive Performance Milestone at any time without liability to Owner by written notice to Contractor.

16.4.6 Contractor shall have sole responsibility for the disbursement of the Incentive Payment to its Eligible Personnel and for the payment of all applicable Taxes in connection therewith. Contractor shall have sole responsibility for ensuring that the Incentive Payment is disbursed in accordance with all applicable labor and employment laws and regulations, and agrees to release, indemnify, defend and hold harmless each Owner Indemnitee from and against any and all Losses, of whatsoever kind or nature, which may directly or indirectly arise or result from Contractor’s failure to adhere to the requirements herein. Nothing in this Section 16.4 amends or modifies any obligation of Contractor under Article 24.”

(iii) Exhibit F to the Agreement is hereby amended by inserting a new Exhibit F-19 immediately following Exhibit F-18, in the form attached as Attachment A to this Amendment.

(iv) A new Exhibit Z to the Agreement is attached as Attachment B to this Amendment.

 

3


 

3. Benefits. This Amendment shall inure to the benefit of and be binding upon the Parties and their respective successors and permitted assigns. Except with respect to the rights of successors and permitted assigns as provided in the Agreement, including any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders), nothing express or implied in this Amendment is intended to confer upon any person, other than the Parties and their respective successors and assigns, any rights, remedies, obligations or liabilities under or by reason of this Amendment.

4. Effect of Amendment. Except as specifically set forth herein, the Agreement, as amended by this Amendment, remains in full force and effect in accordance with its terms.

5. Governing Law. This Amendment shall in all respects be governed by, and construed in accordance with the laws of the State of New York without regard to principles of conflicts of laws.

6. Counterparts. This Amendment may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute one and the same instrument. A signed copy of this Amendment transmitted by facsimile or email shall be treated as an original and shall be binding against the Party whose signature appears on such copy.

[signatures appear on following page]

 

4


 

IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their duly authorized representatives as of the Effective Date.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC
By: /s/ Keith Larson             
Name: Keith Larson
Title: Secretary
KZJV LLC
By: /s/ Paul Fellows             
Name: Paul Fellows
Title: Manager
By: /s/ Matt Key               
Name: Matt Key
Title: Manager

 

5


 

Attachment A

EXHIBIT F-19

FORM OF CERTIFICATE OF INCENTIVE PERFORMANCE MILESTONE ACHIEVEMENT

[Omitted]


 

Attachment B

EXHIBIT Z

INCENTIVE PERFORMANCE MILESTONE, INCENTIVE LEVELS AND ELIGIBLE POSITIONS

[Omitted]

 

1

Exhibit 10.21

Execution Version

AMENDMENT NO. 2 TO

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

THIS AMENDMENT NO. 2 TO ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Amendment”), entered into and effective as of July 2, 2024 (the “Effective Date”), by and between VENTURE GLOBAL PLAQUEMINES LNG, LLC, a Delaware limited liability company (“Owner”), and KZJV LLC, a Texas limited liability company (“Contractor”).

W I T N E S S E T H

WHEREAS, Owner and Contractor are parties to that certain Engineering, Procurement and Construction Agreement dated as of January 10, 2023, as amended by Amendment No. 1 dated as of September 26, 2023 (the “Agreement”): and

WHEREAS, pursuant to Section 41.8 of the Agreement, the Parties desire to amend the Agreement as set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants and provisions herein contained, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby covenant and agree as follows:

1. Defined Terms. Capitalized terms not defined in this Amendment shall have the meaning given to such terms in the Agreement.

2. Amendments. Effective as of November 6, 2023, the Agreement is hereby amended as follows:

(i) Exhibit K to the Agreement is deleted in its entirety and replaced with the document included herein as Attachment A to this Amendment.

(ii) Exhibit C to the Agreement is deleted in its entirety and replaced with the document included herein as Attachment B to this Amendment.

3. Benefits. This Amendment shall inure to the benefit of and be binding upon the Parties and their respective successors and permitted assigns. Except with respect to the rights of successors and permitted assigns as provided in the Agreement, including any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders), nothing express or implied in this Amendment is intended to confer upon any person, other than the Parties and their respective successors and assigns, any rights, remedies, obligations or liabilities under or by reason of this Amendment.

4. Effect of Amendment. Except as specifically set forth herein, the Agreement, as amended by this Amendment, remains in full force and effect in accordance with its terms.

 

1


Execution Version

 

5. Governing Law. This Amendment shall in all respects be governed by, and construed in accordance with the laws of the State of New York without regard to principles of conflicts of laws.

6. Counterparts. This Amendment may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute one and the same instrument. A signed copy of this Amendment transmitted by facsimile or email shall be treated as an original and shall be binding against the Party whose signature appears on such copy.

[signatures appear on following page]

 

2


Execution Version

 

IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their duly authorized representatives as of the Effective Date.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC
By: /s/ Keith Larson             
Name: Keith Larson
Title: Secretary
KZJV LLC
By: /s/ Paul Fellows             
Name: Paul Fellows
Title: Manager
By: /s/ Matt Key               
Name: /s/ Matt Key
Title: Manager

 

3


Execution Version

 

Attachment A

EXHIBIT K

LIST OF CONTRACTOR’S KEY PERSONNEL

[Omitted]


Execution Version

 

Attachment B

Revised Exhibit C

[Omitted]

Execution Version

 

Exhibit 10.22

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

between

VENTURE GLOBAL CP2 LNG, LLC

as Owner

and

WORLEY FIELD SERVICES INC.

as Contractor

Dated as of May 12, 2023

RELATING TO PHASE 1 OF THE LNG EXPORT AND LIQUEFACTION FACILITY

TO BE LOCATED ON THE CALCASIEU SHIP CHANNEL

IN CAMERON PARISH, LOUISIANA

 


Execution Version

TABLE OF CONTENTS

 

               Page  

1.

   DEFINITIONS      1  

2.

   AGREEMENT; EXHIBITS; CONFLICTS      23  
   2.1    LANGUAGE OF AGREEMENT      23  
   2.2    PRECEDENCE OF AGREEMENT      23  
   2.3    INTERPRETATION      24  
   2.4    NEGOTIATION AND DOCUMENTATION OF THIS AGREEMENT      25  

3.

   GENERAL PROVISIONS      25  
   3.1    WORK TO BE PERFORMED      25  
   3.2    GENERAL OVERSIGHT AND ACCESS      26  
   3.3    JOB SITE CONDITIONS      26  
   3.4    OWNER NOT RESPONSIBLE FOR ACTS OF CONTRACTOR; CONTRACTOR NOT RESPONSIBLE FOR OWNER SCOPE OF WORK      27  
   3.5    EFFECT OF AND TIME FOR OWNER REVIEW OF DOCUMENTS      28  
   3.6    CLAIMS UPON FAILURE OF MATERIAL      28  
   3.7    RESPONSIBILITIES OF OWNER      28  
   3.8    RESPONSIBILITIES OF CONTRACTOR      30  
   3.9    SPARE PARTS      38  
   3.10    PROCUREMENT      39  

4.

   COMMENCEMENT OF THE WORK      39  
   4.1    NOTICE TO PROCEED      39  
   4.2    LIMITED NOTICES TO PROCEED      40  

5.

   PERSONNEL AND QUALIFICATIONS      40  
   5.1    GENERAL      40  
   5.2    KEY PERSONNEL      41  

6.

   PRICE AND PAYMENT      41  
   6.1    TARGET PRICE      41  
   6.2    [RESERVED]      42  
   6.3    PAYMENT      42  
   6.4    ENCUMBRANCES      45  
   6.5    DEFICIENT REQUESTS FOR PAYMENT      46  
   6.6    OWNER PAYMENT OBLIGATIONS      46  

 

i


Execution Version

 

   6.7    FINAL PAYMENT      46  
   6.8    OWNER’S RIGHT TO WITHHOLD PAYMENT      47  
   6.9    RELEASE OF LIABILITY      48  

7.

   SCHEDULE BONUSES      48  
   7.1    INTERIM MILESTONE BONUSES      48  
   7.2    PRIMARY MILESTONE BONUSES      49  
   7.3    SUPER PRIMARY MILESTONE BONUSES      49  
   7.4    LIMITATIONS      50  

8.

   COST OVERRUN; COST SAVINGS      51  
   8.1    TOTAL COSTS      51  
   8.2    COST OVERRUN      52  
   8.3    COST SAVINGS      53  

9.

   PERFORMANCE SECURITY      53  
   9.1    TYPES OF PERFORMANCE SECURITY      53  
   9.2    PERFORMANCE AND PAYMENT BONDS      53  
   9.3    CONTRACTOR GUARANTEES      54  

10.

   QUALITY CONTROL AND INSPECTION      55  
   10.1    QUALITY MANAGEMENT PLAN      55  
   10.2    DEFECTS AND DEFICIENCIES      55  
   10.3    INSPECTION RIGHTS      56  
   10.4    THIRD PARTY INSPECTION      56  
   10.5    EFFECT OF WAIVER OF INSPECTION RIGHTS      57  

11.

   HEALTH, SAFETY, SECURITY AND ENVIRONMENT      57  
   11.1    COMPLIANCE      57  
   11.2    HSSE PROGRAM      57  
   11.3    SAFEGUARDS      58  
   11.4    HSSE INCIDENTS      58  

12.

   CHANGES IN THE WORK      59  
   12.1    GENERAL      59  
   12.2    CHANGE ORDER PROCESS      60  
   12.3    DISPUTED CHANGES      62  
   12.4    CHANGES DUE TO UNKNOWN SUBSURFACE CONDITIONS      62  
   12.5    INFORMATION REQUESTS      63  

 

ii


Execution Version

 

13.

   PROJECT SCHEDULE AND MONTHLY PROGRESS REPORTS      63  
   13.1    GENERAL      63  
   13.2    PROJECT SCHEDULE      63  
   13.3    MONTHLY PROGRESS REPORTS      63  

14.

   TRAINING      64  

15.

   TESTING      64  
   15.1    FACTORY TESTS      64  
   15.2    DEMONSTRATION TESTING      65  
   15.3    PERFORMANCE TESTING      65  
   15.4    CORRECTION OF PERFORMANCE DEFECTS OR DEFICIENCIES      67  

16.

   TIME FOR PERFORMANCE AND SCHEDULE      68  
   16.1    TIME FOR COMPLETION      68  
   16.2    FAILURE TO MITIGATE      68  
   16.3    RECOVERY AND ACCELERATION OF WORK      69  

17.

   SUSPENSION OR REJECTION OF THE WORK      69  
   17.1    GENERAL      69  
   17.2    COMPENSATION TO CONTRACTOR FOR SUSPENSION      70  
   17.3    REJECTION OF WORK      70  
   17.4    CORRECTION OF WORK OR MATERIAL      71  
   17.5    FAILURE TO CORRECT MATERIAL      71  
   17.6    OTHER MATERIAL OR WORK DAMAGED      71  

18.

   LNG PRODUCTION SYSTEM COMPLETION      71  
   18.1    LNG PRODUCTION SYSTEM MECHANICAL COMPLETION      71  
   18.2    LNG PRODUCTION SYSTEM RFSU      72  
   18.3    LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION      73  

19.

   FACILITY COMPLETION      74  
   19.1    FACILITY MECHANICAL COMPLETION      74  
   19.2    FACILITY SUBSTANTIAL COMPLETION      75  
   19.3    READY FOR SHIP LOADING      76  
   19.4    FINAL COMPLETION      76  
   19.5    PUNCH LIST ITEMS      78  

20.

   WARRANTY FOR DEFECTS      78  
   20.1    IN GENERAL      78  

 

iii


Execution Version

 

   20.2    SPECIFIC WARRANTIES      79  
   20.3    NOTICE OF DEFECTS OR DEFICIENCIES      80  
   20.4    EXTENSION OF WARRANTY PERIOD      80  
   20.5    FAILURE TO REMEDY DEFECTS      80  
   20.6    REMOVAL AND OWNERSHIP OF DEFECTIVE WORK      81  
   20.7    FURTHER TESTS      81  
   20.8    RIGHT OF ACCESS      81  
   20.9    SUBCONTRACTOR WARRANTIES      81  
   20.10    NO IMPLIED WARRANTIES      82  
   20.11    REPAIRS AND TESTING BY OWNER      82  
   20.12    SURVIVAL OF WARRANTIES      82  

21.

   LIABILITY      83  
   21.1    TOTAL LIABILITY CAP      83  
   21.2    NO CONSEQUENTIAL DAMAGES      83  

22.

   PERFORMANCE TESTS; LIQUIDATED DAMAGES      84  
   22.1    PERFORMANCE TESTS      84  
   22.2    SCHEDULE DELAY LIQUIDATED DAMAGES FOR FAILURE TO ACHIEVE LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION OR FACILITY SUBSTANTIAL COMPLETION BY AN APPLICABLE DEADLINE      84  
   22.3    LIQUIDATED DAMAGES CAP      87  
   22.4    PAYMENT      88  
   22.5    LIQUIDATED DAMAGES REASONABLE      88  
   22.6    EFFECT ON OTHER PROVISIONS      88  

23.

   SUBCONTRACTORS      89  
   23.2    CONTRACTOR RESPONSIBLE FOR WORK      90  
   23.3    ASSIGNMENT      90  

24.

   LABOR RELATIONS      91  
   24.1    GENERAL MANAGEMENT OF EMPLOYEES      91  
   24.2    WAGES AND CONDITIONS      91  
   24.3    VIOLATIONS      91  
   24.4    DISPUTES      91  
   24.5    STATUTORY EMPLOYER      91  
   24.6    LOCAL LABOR      92  
   24.7    COMMUNITY IMPACTS      92  

 

iv


Execution Version

 

               Page  

25.

   TITLE AND RISK OF LOSS      92  
   25.1    TRANSFER OF TITLE      92  
   25.2    RISK OF LOSS      93  
   25.3    PROTECTION OF OWNER      93  

26.

   INSURANCE      93  
   26.1    IN GENERAL      93  
   26.2    POLICIES TO BE OBTAINED BY CONTRACTOR      94  
   26.3    POLICIES TO BE OBTAINED BY OWNER      99  

27.

   CONFIDENTIAL TREATMENT OF PROPRIETARY INFORMATION; RELIANCE ON INFORMATION      101  
   27.1    CONFIDENTIAL TREATMENT      101  
   27.2    RELIANCE ON INFORMATION      103  

28.

   REPRESENTATIONS AND WARRANTIES      103  
   28.1    OWNER REPRESENTATIONS AND WARRANTIES      103  
   28.2    CONTRACTOR REPRESENTATIONS AND WARRANTIES      103  

29.

   INTELLECTUAL PROPERTY AND LICENSES      105  
   29.1    OWNERSHIP      105  
   29.2    LICENSES      105  
   29.3    DATA      106  

30.

   INDEMNIFICATION      107  
   30.1    CONTRACTOR INDEMNITY      107  
   30.2    OWNER INDEMNITY      108  
   30.3    ACTIONS BY EMPLOYEES      109  
   30.4    NOTICE AND DEFENSE      109  
   30.5    REMEDIES NOT EXCLUSIVE      110  
   30.6    TAX EFFECT OF INDEMNIFICATION      110  

31.

   EVENTS OF DEFAULT; REMEDIES      110  
   31.1    CONTRACTOR EVENTS OF DEFAULT      110  
   31.2    REMEDIES      112  
   31.3    DAMAGES      113  
   31.4    OWNER REMEDIES      113  
   31.5    OWNER DEFAULT      113  
   31.6    OBLIGATIONS UPON TERMINATION      114  

 

v


Execution Version

 

32.

   TERMINATION FOR CONVENIENCE      115  
   32.1    GENERAL      115  
   32.2    CLAIMS FOR PAYMENT FOLLOWING TERMINATION FOR CONVENIENCE      116  

33.

   FORCE MAJEURE      116  
   33.1    EXTENSION OF TIME FOR FORCE MAJEURE EVENT      116  
   33.2    CONTRACTOR’S RESPONSIBILITY      116  
   33.3    CONTINUING RESPONSIBILITY OF CONTRACTOR      116  
   33.4    PERFORMANCE NOT EXCUSED      116  

34.

   DUTIES AND TAXES      117  
   34.1    ALLOCATION OF RESPONSIBILITIES      117  
   34.2    LOUISIANA TAX AND INCENTIVES PROVISIONS      117  

35.

   BINDING AGREEMENT; ASSIGNMENT      118  
   35.1    BY OWNER      118  
   35.2    BY CONTRACTOR      118  

36.

   DISPUTES      118  
   36.1    DISPUTE RESOLUTION      118  
   36.2    CONTINUATION OF WORK DURING DISPUTE      120  

37.

   INDEPENDENT CONTRACTOR      120  
   37.1    GENERAL      120  
   37.2    EMPLOYEES      120  
   37.3    RESPONSIBILITY FOR SUBCONTRACTORS, ETC      120  

38.

   NOTICES AND COMMUNICATIONS      121  
   38.1    REQUIREMENTS      121  
   38.2    EFFECTIVE TIME      122  
   38.3    TECHNICAL COMMUNICATIONS      122  

39.

   FINANCING MATTERS      122  

40.

   COMPLIANCE WITH LAWS      122  
   40.1    ANTI-CORRUPTION      122  
   40.2    RECORDS      124  
   40.3    EXPORT CONTROLS      124  
   40.4    SUBCONTRACTORS; INDEMNIFICATION      125  

 

vi


Execution Version

 

41.

   MISCELLANEOUS      125  
   41.1    FURTHER ASSURANCES AND EXPENSES      125  
   41.2    RECORD RETENTION      125  
   41.3    NO WAIVER      125  
   41.4    SEVERABILITY      126  
   41.5    BINDING ON SUCCESSORS      126  
   41.6    GOVERNING LAW      126  
   41.7    SET-OFF      126  
   41.8    AMENDMENT      127  
   41.9    HEADINGS FOR CONVENIENCE ONLY      127  
   41.10    NONDISCRIMINATION      127  
   41.11    COUNTERPART EXECUTION      127  
   41.12    THIRD-PARTY BENEFICIARIES      127  
   41.13    SURVIVAL OF OBLIGATIONS      127  
   41.14    ENTIRE AGREEMENT      128  
   41.15    RELATIONSHIP      128  
   41.16    LIMITED RECOURSE      128  

 

 

vii


Execution Version

 

Exhibits:

 

Exhibit A   

Scope of Work; Applicable Codes and Standards

Exhibit B   

Compensation

  
  

Exhibit B-1

  

Direct Costs and Non-Reimbursable Costs

  

Exhibit B-2

  

[Reserved]

  

Exhibit B-3

  

Target Price Components

  

Exhibit B-4

  

Cover Costs Examples

  

Exhibit B-5

  

Payment Procedures

Exhibit C   

Contractor Rates

Exhibit D   

Schedule Milestones

Exhibit E   

Project Schedule

Exhibit F   

Contract Forms

  

Exhibit F-1

  

Form of Contractor Certificate for Partial Waiver of Liens

  

Exhibit F-2

  

Form of Subcontractor Certificate for Partial Waiver of Liens

  

Exhibit F-3

  

Form of Contractor Certificate for Final Waiver of Liens

  

Exhibit F-4

  

Form of Subcontractor Certificate for Final Waiver of Liens

  

Exhibit F-5

  

Form of Consent and Agreement

  

Exhibit F-6

  

Form of Contractor Guarantee

  

Exhibit F-7

  

Form of Request for Payment

  

Exhibit F-8

  

Form of Limited Notice to Proceed

  

Exhibit F-9A

  

Form of Performance Bond

  

Exhibit F-9B

  

Form of Payment Bond

  

Exhibit F-10

  

Form of Change Order

  

Exhibit F-11

  

Form of LNG Production System Mechanical Completion Certificate

  

Exhibit F-12

  

Form of LNG Production System RFSU Certificate

  

Exhibit F-13

  

Form of Notice to Proceed

  

Exhibit F-14

  

Form of Title Insurance Indemnity Undertaking

  

Exhibit F-15

  

Form of Payment Status Affidavit (Contractor)

  

Exhibit F-16

  

Form of Subcontractor’s Payment Status Affidavit

  

Exhibit F-17

  

Form of Certificate of Achievement

  

Exhibit F-18

  

Form of Certificate of Schedule Milestone Achievement

Exhibit G   

Training Requirements

Exhibit H   

Schedule of Major Vendors

Exhibit I   

Progress Reporting and Progress Meetings

Exhibit J   

Document Control and Information Management

Exhibit K   

List of Contractor’s Key Personnel

Exhibit L   

Permits, Licenses and Government Approvals

Exhibit M   

Relied Upon Information

Exhibit N   

Owner Supplied Information

Exhibit O   

Schedule of Major Subcontractors

Exhibit P   

Mechanical Completion, Commissioning, Start-up and Substantial Completion

Exhibit Q   

Owner Personnel

Exhibit R   

Demonstration Tests and Performance Tests

Exhibit S   

LNG Production System Handover Packages

 

1


Execution Version

 

Exhibit T   

Requirements for Simultaneous Operation

Exhibit U   

Health, Safety, Security and Environment Requirements

Exhibit V   

First Fills and Catalysts

Exhibit W   

Open Cost Items

Exhibit X   

Cost Overrun and Cost Savings Adjustments

Exhibit Y   

Coordination Procedure

Exhibit Z   

CP2 Phase 2 EPC Term Sheet

 

2


Execution Version

 

THIS ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Agreement”) is made and entered into as of May 12, 2023 (the “Effective Date”) by and between VENTURE GLOBAL CP2 LNG, LLC (“Owner”), a limited liability company duly organized and validly existing under the laws of the State of Delaware domiciled in and with its principal place of business located at 1001 19th Street North, Suite 1500, Arlington, VA 22209, and WORLEY FIELD SERVICES INC., a corporation duly organized and validly existing under the laws of Texas with its principal place of business at 5995 Rogerdale Rd., Houston, TX 77072 (the “Contractor”).

W I T N E S E T H

WHEREAS, Owner is developing and intends to own and operate natural gas liquefaction facilities, including two phases, an export terminal and LNG storage facilities located on the Calcasieu Ship Channel in Cameron Parish, Louisiana, all as more fully described herein and the Exhibits hereto;

WHEREAS, Owner desires to engage Contractor to perform certain design, engineering, procurement, and construction-related services in respect of the first phase, with a nameplate capacity of fourteen decimal four (14.4) million metric tonnes per annum of LNG, all as more fully described herein and in the Exhibits hereto;

WHEREAS, Contractor has (a) been provided and reviewed the conceptual drawings, the Owner Contracts and the other information relating to the Facility (as hereinafter defined) and all other documents relating to the Facility which Contractor and Owner have deemed necessary in connection with this Agreement, (b) inspected the Job Site (as hereinafter defined), and (c) performed or reviewed such other investigations, studies and analyses, which Contractor has determined to be necessary or prudent, in connection with the performance of the Work (as hereinafter defined);

WHEREAS, Contractor has represented that it is experienced and qualified in providing technical assistance, licensing, engineering, procurement, supply, construction management, construction, Pre-Commissioning (as hereinafter defined), Commissioning (as hereinafter defined) and testing services, and that it possesses the requisite expertise and resources to complete the Work to be performed by it; and

WHEREAS, Contractor desires to complete the Work for Owner.

NOW, THEREFORE, in consideration of the sums to be paid to Contractor by Owner and of the covenants and agreements set forth herein, and for other good and valuable consideration, the receipt and adequacy of which is hereby acknowledged, the Parties hereto, intending to be legally bound, hereby agree as follows:

 

1.

DEFINITIONS.

For all purposes of this Agreement, except as otherwise expressly provided or unless the context otherwise requires, the following terms when capitalized herein (including the Exhibits) shall have the following meanings:


Execution Version

 

Abandonment of the Project” means Contractor’s refusal to perform substantially all home office activities and field construction operations in a manner that manifests the intent by Contractor of not completing the Work under this Agreement.

Affiliate” means, in relation to any Person, any other Person: (a) which directly or indirectly controls, or is controlled by, or is under common control with, such Person; or (b) which directly or indirectly beneficially owns or holds fifty percent (50%) or more of any class of voting stock or other equity interests of such Person; or (c) which has fifty percent (50%) or more of any class of voting stock or other equity interests that is directly or indirectly beneficially owned or held by such Person; or (d) who either holds a general partnership interest in such Person or such Person holds a general partnership interest in the other Person. For purposes of this definition, the word “controls” means possession, directly or indirectly of the power to direct or cause the direction of the management or policies of a Person, whether through the ownership of voting securities or otherwise. For the avoidance of doubt, the Contractor Guarantor shall be deemed to be an Affiliate of Contractor under this Agreement.

Agreement” has the meaning set forth in the introductory paragraph hereof, and shall be deemed to include all Exhibits to this Agreement, as each of the foregoing may be amended, modified and supplemented from time to time pursuant to the terms hereof.

Anti-Corruption Laws” has the meaning set forth in Section 40.1.2.

Applicable Codes and Standards” means those certain codes, requirements and standards applicable to the Facility, the Job Site, the Work, Contractor and/or any Subcontractors set forth in Exhibit A or in any applicable Law. In the event of an inconsistency or conflict between any of the Applicable Codes and Standards, the more stringent standard as contemplated therein shall govern Contractor’s performance under this Agreement.

Applicable Deadline” means an LNG Production System Substantial Completion Deadline, the Facility Substantial Completion Deadline or the Final Completion Deadline, as applicable.

Base Target Price” means, as of any date, an amount equal to the sum of the Direct Costs (other than Tax Costs) components of the Target Price as of such date.

BH” means Baker Hughes Energy Services LLC, a Delaware limited liability company.

BH Testing Delay” has the meaning set forth within the definition of Owner Caused Delay.

Block” means a grouping of two (2) Liquefaction Trains in a Liquefaction Train System.

Btu” or “British Thermal Unit” means the amount of heat required to raise the temperature of one avoirdupois pound of pure water from fifty-nine degrees (59°) Fahrenheit to sixty degrees (60°) Fahrenheit at a pressure of fourteen point six nine six (14.696) pounds per square inch absolute (psia).

 

2


Execution Version

 

Business Day” means any Day other than a Saturday, Sunday or a legal holiday in the State of New York (solely for the purpose of a payment obligation) or the State of Louisiana (with respect to all other obligations).

Certificate of Achievement” means the certificate, in substantially the form set forth as Exhibit F-17, to be provided by Contractor confirming in writing that the particular Margin Milestone has been achieved and explaining how it was achieved.

Certificate of Schedule Milestone Achievement” means the certificate, in substantially the form set forth as Exhibit F-18, to be provided by Contractor confirming in writing that the particular Schedule Milestone has been achieved and explaining how it was achieved.

Change in Law” means (a) the enactment or issuance of any new Law or Permit applicable to the Facility, the Job Site and/or the Parties, (b) the amendment, alteration, modification or repeal of any existing Law or Permit applicable to the Facility (including any change to Facility noise or emissions limitations), the Job Site and/or the Parties, or (c) any authoritative interpretation of any existing Law or Permit applicable to the Facility, the Job Site and/or the Parties, expressed in writing and issued by a Government Authority that is contrary to the existing official interpretation thereof, which in the case of any of (a), (b) or (c) above is enacted or adopted and is imposed and/or comes into effect after the Effective Date, and that must be complied with in order for the Facility to be constructed or operated lawfully; provided, however, that any change in any Law relating to income, capital, net worth or income withholding taxes shall not constitute a Change in Law for purposes hereof.

Change Order” means a document issued pursuant to Article 12 which authorizes, as applicable, a change in or to (a) the Work or the requirements set forth in Exhibit A, (b) the Target Price, (c) the Project Schedule, (d) the Critical Path, (e) an Applicable Deadline, (f) the Demonstration Tests; (g) Performance Tests (or protocol therefor); or (h) any right, liability or obligation of a Party or any other provision hereof, and is in the form attached hereto as Exhibit F-10.

Commissioning” means the commissioning activities performed by Contractor with respect to an LNG Production System after LNG Production System Mechanical Completion and Pre-Commissioning for such LNG Production System has occurred, as set forth in Exhibit P and Owner has accepted a Ready for Commissioning Certificate for such LNG Production System in accordance with Exhibit P. Commissioning includes all of the activities that are required to be completed in order to put the equipment and facilities into operation, to dynamically verify functionality of equipment and to ensure that systems, or facilities forming part of a system, are in accordance with specified requirements to bring that system into operation, including specialist flushing and cleaning, chemical and hydraulic cleaning, drying, oxygen freeing nitrogen and helium testing.

Completion Date” means the applicable Schedule Milestone Completion Date as set forth in Exhibit D – Appendix 2, or any of them as the context may require.

Confidential Information” has the meaning set forth in Section 27.1.

Consent and Agreement” has the meaning set forth in Article 39.

 

3


Execution Version

 

Contractor” has the meaning set forth in the introductory paragraph hereof, and includes legal successors and permitted assigns as may be accepted by Owner, in writing, pursuant to the terms of this Agreement.

Contractor Confidential Information” has the meaning set forth in Section 27.1.2.

Contractor Guarantee” means the guarantee issued by the Contractor Guarantor in the form of Exhibit F-6.

Contractor Guarantor” means Worley Limited.

Contractor Indemnitee” means Contractor, the Contractor’s Representative, and all Affiliates, officers, directors, employees and agents thereof.

Contractor Intellectual Property” means all Intellectual Property that is (a) (i) owned by or licensed to Contractor as of the Effective Date or by Contractor’s Affiliates as of the Effective Date or (ii) acquired during the term of this Agreement other than in connection with the Work, (b) disclosed by Contractor hereunder, and (c) necessary for, or used or held for use by Contractor and/or any Subcontractor in connection with the performance, completion, design, construction, installation, operation, maintenance, repair, replacement, modification, alteration or reconstruction of the Work.

Contractor’s G&A” means, in respect of each month that Contractor is eligible for reimbursement of Direct Costs, Contractor’s general and administrative expenses for such month, which shall be a fixed percentage during the term hereof and equal at all times to (i) [***] of the sum of the amount of Direct Costs (other than Tax Costs) that are reimbursable to Contractor in respect of such month plus (ii) [***] of the sum of the amount of Tax Costs that are reimbursable to Contractor in respect of such month, all as specifically defined in Exhibit B-1.

Contractor’s Margin” means, in respect of each month that Contractor is eligible for reimbursement of Direct Costs, Contractor’s profit margin for such month in respect of such Direct Costs, which shall be equal at all times to the sum of the amount of Direct Costs that are reimbursable to Contractor in respect of such month multiplied by the Margin Percentage all as specifically defined in Exhibit B-1. In respect of each Margin Milestone, the payment of Contractor’s Margin for such Margin Milestone shall be calculated as follows:

CM = Base Target Price x MP x FP

Where:

CM = Contractor’s Margin for the relevant Margin Milestone

MP = the Margin Percentage, as adjusted pursuant to Section 8.2.

FP = the fixed milestone percentage for the relevant Margin Milestone set forth in Appendix 1 of Exhibit D.

 

4


Execution Version

 

Contractor’s Representative” means Contractor’s employee designated by Contractor pursuant to Section 3.8.32.

Contractor Taxes” has the meaning set forth in Section 34.1.

Corrective Work” has the meaning set forth in Section 20.1.3.

Cost Overrun” means an amount equal to the amount by which the Total Costs less Contractor’s Margin exceeds the Target Price less Contractor’s Margin.

Cost Savings” means an amount equal to the amount by which the Target Price exceeds the Total Costs.

Cover Costs” has the meaning set forth in Section 31.3.

CP Express Pipeline” means, collectively, the natural gas pipelines interconnected with the Facility, as more specifically described in Exhibit A.

Critical Path” means the longest duration series of interdependent engineering, procurement, construction, Pre-Commissioning, Commissioning and testing activities described in or prepared in accordance with Exhibit E relating to the Work logically connected end to end using critical path method precedence networking techniques that determines the shortest total duration of the Project Schedule from the commencement of the Work to Facility Substantial Completion or Applicable Deadline, if different, which techniques shall be agreed to in writing by Owner and Contractor prior to the Notice to Proceed Date.

Day” or “day” means a period of twenty-four (24) consecutive hours from 12:00 midnight (Central time), and shall include Saturdays, Sundays and all holidays except that in the event a time period set forth herein expires on a Day that is not a Business Day, such period shall be deemed to expire on the next Business Day thereafter.

Defects” or “Deficiencies” means any components, tools, Materials, installation (including the installation and integration of Owner Furnished Equipment and Materials by Contractor or its Subcontractors), construction, workmanship or Work (including any Corrective Work) that, in Owner’s reasonable judgment, (a) do not conform to the terms of this Agreement or any Warranty or (b) are not of uniform good quality, or designs which fail to conform to the Applicable Codes and Standards, Owner Standards and all other requirements of this Agreement, including Exhibit A (to the extent designed by Contractor or its Subcontractors), application, manufacture or workmanship, or that contain improper or inferior workmanship. Defects and Deficiencies shall not be deemed to include breakdown or damage caused by (i) Owner’s negligence or willful misconduct, (ii) Owner’s failure to supply Owner Furnished Equipment and Materials, or failure of the Owner Furnished Equipment and Materials to perform in accordance with the applicable Owner Contract pursuant to which such Owner Furnished Equipment and Materials were purchased by Owner, or Owner’s failure to perform the Owner Scope of Work, (iii) Owner’s failure to operate or maintain an LNG Production System or the Facility in accordance with operations and maintenance manuals provided to Owner by Contractor, (iv) any repair, alteration or modification by third parties (unless such third party was approved by Contractor or was retained by Owner to perform such repair, alteration or modification in

 

5


Execution Version

 

accordance with this Agreement where Contractor failed to initiate correction of Work), (v) normal wear and tear, or (vi) any effects of the elements on, or use outside of the design parameters of, an LNG Production System or the Facility, including distortion, corrosion, abrasion, material changes to the operating conditions (such as temperature, pressure, or changes in material product composition).

Deliverables” means all Drawings and Specifications, records, manuals, programs, registers and written procedures required pursuant to the terms of this Agreement (including Exhibit Y) or otherwise to operate and maintain the Work and the Facility and training of the Facility’s operation and maintenance personnel via classroom and hands-on sessions pursuant to the terms hereof, excluding Deliverables provided under the Owner Contracts.

Demonstration Tests” has the meaning set forth in Exhibit R.

Direct Costs” means the actual, verifiable and documented costs incurred by Contractor with respect to the performance of the Reimbursable Work based upon the labor rates, unit rates and actual out-of-pocket costs and expenses, in each case, as described in more particular detail in Exhibit B-1 and Exhibit C and that are incurred by Contractor in accordance with this Agreement, excluding any Non-Reimbursable Costs.

Dispute” has the meaning set forth in Section 36.1.1.

Dollar” and “$” means the lawful currency of the United States of America.

Drawings and Specifications” means all specifications, calculations, designs, plans, drawings, engineering and analyses, operation and maintenance manuals, original equipment manufacturer manuals, material safety data sheets, operating instructions, system checklists, startup procedures, Pre-Commissioning, Commissioning procedures and checklists, System Turnover Packages, alignment checklists and all other documents of the Work, including the structure and foundation thereof, either (a) described in or attached to this Agreement or (b) prepared or modified by Contractor or any Subcontractor with respect to the Work, excluding Drawings and Specifications provided under the Owner Contracts.

EAR” has the meaning set forth in Section 40.3.1.

Effective Date” has the meaning set forth in the preamble.

Environmental Laws” means any Law relating to the regulation or protection of human health, safety, natural resources or the environment or to the remediation, manufacture, generation, production, installation, use, sale, storage, treatment, transportation, Release, threatened Release, exposure to, or disposal of Hazardous Substances.

Estimated Monthly Amount” has the meaning set forth in Section 6.3.1.

Export Controls” has the meaning set forth in Section 40.3.1.

Facility” means (a) the first phase of Owner’s CP2 LNG export terminal and liquefaction project, with a nameplate capacity of fourteen decimal four (14.4) MTPA of LNG, to be located

 

6


Execution Version

 

at the Job Site and more specifically described as the fully operational, complete project (including Materials and Owner Furnished Equipment and Materials incorporated therein) to be designed, engineered, procured, constructed, pre-commissioned, tested, delivered and warranted under this Agreement in order to successfully pass the Performance Tests and meet or exceed the requirements set forth in Exhibit A, and consisting of the Liquefaction Train System, the LNG Storage Tanks, the Pre-Treatment System and the marine terminal and including all Materials necessary to safely and efficiently transport and process Feed Gas through each LNG Production System, load and store LNG in the LNG Storage Tanks, transport LNG to, and load LNG on, an LNG Tanker, and otherwise process, transport, store load and unload LNG and Feed Gas, all as more particularly described in Exhibit A together with the supporting improvements and interconnections related thereto, as specifically addressed in the Exhibits hereto, and (b) the Power Plant.

Facility Mechanical Completion” means the acceptance by Owner of the Facility after satisfaction of the applicable conditions set forth in Exhibit P and Section 19.1.

Facility Mechanical Completion Date” means the date on which Facility Mechanical Completion occurs in accordance with Section 19.1.

Facility Performance Tests” has the meaning set forth in Section 15.3.4.

Facility Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.5 as liquidated damages for the delay in the achievement of Facility Substantial Completion.

Facility Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(e).

Facility Substantial Completion” means the completion of the Facility in accordance with and to the extent set forth in Section 19.2.

Facility Substantial Completion Date” means the date on which Facility Substantial Completion occurs in accordance with Section 19.2.

Facility Substantial Completion Deadline” means the date identified on Exhibit D.

Feed Gas” means natural gas, in gaseous form, which consists of gas transported by natural gas pipelines in the United States of America.

Feed Gas Interconnection” means the installation of the Materials to the Pipeline Tie Point(s) and all other activities necessary to effect interconnection of the Facility with the civil, mechanical, electrical and control systems of the CP Express Pipeline.

FERC” means the Federal Energy Regulatory Commission and its successors.

FERC Authorization” means the authorization by FERC granting to Owner the approvals requested in that certain application filed by Owner with FERC in FERC Docket #CP22-21-000 (as may be amended from time to time) pursuant to Section 3(a) of the Natural Gas Act and the corresponding regulations of FERC.

 

7


Execution Version

 

Field Services Agreement” means the Field Services Agreement to be entered into by Owner and BH (or BH’s Affiliate).

Final Completion” means the completion of the Facility in accordance with and to the extent set forth in Section 19.4.

Final Completion Date” means the date on which Final Completion occurs in accordance with Section 19.4.

Final Completion Deadline” means the date that is [***] days after the Facility Substantial Completion Date.

Final Request for Payment” has the meaning set forth in Section 6.7.

Financial Closing Date” means the closing date for the Financing by the Lenders, at which time all conditions precedent to the drawing of funds thereunder have been satisfied or waived and the initial funds contemplated by the Financing are disbursed to Owner.

Financing” has the meaning set forth in Article 39.

Financing Deliverables” has the meaning set forth in Article 39.

Force Majeure Event” means any act, event or condition that (a) arises after the Effective Date, and (b) has an impact which will actually, demonstrably and adversely affect a Party’s ability to perform its obligations in accordance with this Agreement (excluding obligations to pay money due) or will actually, demonstrably and adversely affect the Critical Path, in each case, to the extent that such act, event or condition (i) is beyond the reasonable control of the Party relying thereon, (ii) is not the result of any unreasonable acts, omissions or delays of the Party relying thereon (or any Third Party over whom such Party has control, including any Subcontractor), (iii) is not an act, event or condition, the risks or consequences of which such Party has expressly agreed to assume hereunder, or (iv) that could not be avoided by the exercise of reasonable precautions, efforts and measures (including planning, scheduling and rescheduling), whether before, after or during such act, event or condition. “Force Majeure Event” includes the following (if the conditions and requirements described above are satisfied): hurricanes, named tropical storms, floods, storm surge, tsunamis, lightning strike, volcanic eruptions, tornados, or other unusually severe conditions; government decreed official state of emergency or other governmental action of a Government Authority; fire, earthquakes and explosions; epidemics (including the epidemic known as COVID-19); contamination by nuclear, chemical, or biological cause; acts of war (whether declared or undeclared); accidents of navigation; sabotage or terrorism; and strikes, work stoppages or other labor actions that are not directed solely at Contractor or any Subcontractor; and Change in Law. Notwithstanding the foregoing, “Force Majeure Event” does not include (i) strikes, work stoppages (or deteriorations), slowdowns or other labor actions directed solely at Contractor or any Subcontractor solely involving the employees of Contractor or any Subcontractor, (ii) weather conditions (other than those expressly defined as Force Majeure Events above) which could reasonably be anticipated by experienced professional design and construction

 

8


Execution Version

 

contractors familiar with building comparable facilities on the Gulf Coast of the United States of America, (iii) any Job Site Condition or event arising therefrom, (iv) the occurrence of any manpower, craft labor or Materials shortages (unless otherwise caused by a Force Majeure Event), (v) any failure by Contractor to obtain and/or maintain any Permit it is required to obtain and/or maintain hereunder, (vi) any delay, default or failure (direct or indirect) in obtaining Materials or of any Subcontractor or any other delay, default or failure (financial or otherwise) of a Subcontractor (unless otherwise caused by a Force Majeure Event), or (vii) changes in market conditions.

Gas Turbine” means that component of the Power Plant which generates power to drive a generator by exhausting gases produced by the combustion of fuel and compressed air through a Brayton cycle turbine.

Geotechnical Reports” means those reports furnished by Owner to Contractor prior to the execution of this Agreement, as further described in Exhibit M.

Government Authority” means any agency, authority, department, court, tribunal, ministry, legislative body, commission, instrumentality, public person, statutory or legal entity, person (whether autonomous or not), or other subdivisions of any of the above having a regulatory interest in or jurisdiction over any Party, the Job Site, the performance of the Work, or the Facility (or the construction or operation thereof).

Government Official” has the meaning set forth in Section 40.1.3.

Hazardous Substances” means any element, compound, mixture, solution, particle or substance:

(a) which is or may become dangerous, harmful or potentially dangerous or harmful to the health and welfare of life, natural resources or the environment, such as, but not limited to, explosives, petroleum products, radioactive, corrosive, flammable, infectious, carcinogenic, or mutagenic materials, hazardous wastes, toxic substances and related materials, and including any substance or material included within the definitions of “hazardous substances,” “hazardous wastes,” “solid wastes,” “hazardous materials,” “chemical substances,” “hazardous pollutants” or “toxic pollutants” in any Law, including any Law relating to the protection of human health, natural resources or the environment;

(b) the presence or Release of which requires investigation or remediation under any applicable Law;

(c) which is listed, defined, regulated or forms the basis for liability under any applicable Law relating to the protection of human health, natural resources or the environment; or

(d) the presence of which on the Job Site causes or threatens to cause a nuisance upon the Job Site or to the adjacent properties or poses or threatens to pose a hazard to the health or safety of Persons on or about the Job Site or on or about the adjacent properties.

HSSE” has the meaning set forth in Section 11.2.2.

 

9


Execution Version

 

HSSE Program” has the meaning set forth in Section 11.2.1.

ICC” means the International Chamber of Commerce.

Indemnified Liens” has the meaning set forth in Section 6.4.1.

Independent Engineer” means the engineering firm designated by the Lenders to monitor the progress of the Work and conformity of the Work with Owner Standards and the requirements and specifications contained herein.

Initial Request for Payment” means the first Request for Payment that is issued simultaneously with the Notice to Proceed.

Intellectual Property” means all United States and foreign intellectual property, including all (a) inventions (whether or not patentable or reduced to practice), improvements, patents and industrial designs (including utility models, designs, and industrial property) and patent and industrial design applications, and inventions and patent disclosures, together with all renewals, reissues, reexaminations, provisionals, divisionals, revisions, continuations, continuations-in-part, and extensions thereof; (b) works of authorship (whether or not copyrightable), registered and unregistered copyrights, mask works, database rights, and moral rights, together with all applications therefor and renewals thereof; (c) trade secrets, confidential or proprietary information (including unpublished patent applications, technical data, customer and suppliers lists, pricing and cost information, and business and marketing plans and proposals), technology, know-how, processes, techniques, protocols, specifications, data, compositions, industrial models, architectures, layouts, designs, drawings, plans, ideas, research and development, formulae, algorithms, models, and methodologies; and (d) trademarks, service marks, trade names, domain names, designs, trade dress, business names, corporate names, logos, slogans, and all other indicia of origin, together with all goodwill, registrations, renewals, and applications relating to the foregoing.

Intellectual Property Claim” means any claim, demand, suit or legal action to the extent arising out of or based on any actual or alleged unauthorized disclosure, use or misappropriation of any Intellectual Property, or any actual or alleged infringement or other violation of any right in, to or under, any Intellectual Property of any other Person that: (a) concerns any Materials, Deliverables, Inventions or other services or information provided by Contractor, any of its Affiliates, or any Subcontractor under this Agreement; (b) is based upon or arises out of the performance of the Work by Contractor, any of its Affiliates, or any Subcontractor, including the use of any tools or other implements of construction by Contractor, any of its Affiliates or any Subcontractor; (c) is based upon or arises out of the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem or component thereof) by Contractor or any of its respective Affiliates or Subcontractors under this Agreement or their use of any Contractor Intellectual Property in connection therewith; or (d) is based upon or arises out of Owner’s exercise of its rights pursuant to and in accordance with Article 29, and excluding for the avoidance of doubt any claim, demand, suit or legal action arising out of or based on the Owner Furnished Equipment and Materials.

 

10


Execution Version

 

Interim Milestone” means a Schedule Milestone identified as an Interim Milestone on Appendix 2 of Exhibit D.

Interim Milestone Bonus” means a bonus payment in an amount equal to [***], as such amount may be adjusted pursuant to Sections 7.1.1 and 7.1.3.

Inventions” has the meaning set forth in Section 29.1.

Job Site” means the portion of Owner’s real property interests on which the Facility is to be located, plus the laydown areas, rights-of-way, easements and other property rights affixed, connected or associated therewith and such additional areas as may, from time to time, be designated in writing by Owner for Contractor’s use hereunder, including all roads connecting the Job Site to the MOF Facilities, as more fully described in Exhibit A.

Job Site Conditions” has the meaning set forth in Section 3.3.

Key Personnel” means the employees of Contractor named in Exhibit K.

Late Payment Rate” means the lesser of (a) two percent (2%) above the per annum Prime Rate reported daily in The Wall Street Journal, or (b) the maximum rate permitted by Law.

Law” means (a) any applicable statute, law, common law, rule, regulation, code, ordinance, judgment, decree, writ, order or the like of any Government Authority and the official interpretations thereof or (b) any official requirements or conditions on or with respect to the issuance, maintenance or renewal of any applicable Permit issued by any Government Authority including laws related to Taxes, import or export charges (including any tariffs, levies and duties).

Lenders” means (a) any Person that does or proposes to provide Financing in respect of the Facility and/or the general business and operations of Owner or its Affiliates (including any refinancing thereof), including any export credit agency, funding agency, bondholder, insurance agency, underwriter, investor, commercial lender or similar institution, together with any agent or trustee for such Person, and (b) any provider of any hedging arrangement entered into in connection with the arrangements described in clause (a) above, including an interest rate swap transaction or a forward interest rate swap transaction, in each case, together with any agent or trustee for such provider.

Limited Notice to Proceed” has the meaning set forth in Section 4.2.1.

Liquefaction Train” means the Mixed Refrigerant compression package, including the cold box, surge vessel and other equipment producing approximately [***] MTPA of LNG at design outlet pressure and ambient design conditions of [***] degrees Fahrenheit and [***] relative humidity, at sea level, as further described in Exhibit A.

Liquefaction Train System” means the Mixed Refrigerant compression package, including the cold box, surge vessel and other equipment in a configuration of twenty-six (26) Liquefaction Trains capable of producing an aggregate of approximately [***] MTPA of LNG at design conditions, as further described in Exhibit A and Exhibit R.

 

11


Execution Version

 

LNG” means liquefied natural gas meeting the requirements described in Exhibit A.

LNG Production System” means LPS1, LPS2, LPS3 or LPS4, as applicable.

LNG Production System Handover Package” means, with respect to each of LPS1, LPS2, LPS3 or LPS4, the equipment, Materials and Owner Furnished Equipment and Materials described in Exhibit S.

LNG Production System Mechanical Completion” means the acceptance by Owner of an LNG Production System after satisfaction of the applicable conditions set forth in Section 18.1 and Exhibit P.

LNG Production System Mechanical Completion Certificate” means the certificate provided by Contractor in the form of Exhibit F-11 certifying the satisfaction of each of the requirements required to achieve LNG Production System Mechanical Completion in Section 18.1.

LNG Production System Mechanical Completion Date” means, with respect to an LNG Production System, the date on which LNG Production System Mechanical Completion of such LNG Production System occurs in accordance with Section 18.1.

LNG Production System RFSU” means, with respect to an LNG Production System, all of the following conditions are satisfied: (a) Contractor has completed all applicable Work in accordance with this Agreement, including Exhibit P, to ensure that such LNG Production System is ready to receive and utilize Feed Gas, (b) Contractor has achieved LNG Production System Mechanical Completion, and (c) Contractor has delivered to Owner an LNG Production System RFSU Certificate, as required in Section 18.2.

LNG Production System RFSU Certificate” means the certificate provided by Contractor in the form of Exhibit F-12 in advance of the introduction of Feed Gas for Commissioning.

LNG Production System Substantial Completion” means the completion of an LNG Production System in accordance with and to the extent set forth in Section 18.3.

LNG Production System Substantial Completion Date” means, with respect to an LNG

Production System, the date on which LNG Production System Substantial Completion of such LNG Production System occurs in accordance with Section 18.3.

LNG Production System Substantial Completion Deadline” means the LPS1 Substantial Completion Deadline, the LPS2 Substantial Completion Deadline, the LPS3 Substantial Completion Deadline or the LPS4 Substantial Completion Deadline, as applicable.

LNG Storage Tank” means one (1) of the two (2) cryogenic LNG storage tanks designed and field erected in accordance with the LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 1) to be entered into by and between CB&I LLC and Owner, as more particularly described in Exhibit A.

LNG Storage Tank Cooldown” has the meaning set forth in Section 18.2.2.

 

12


Execution Version

 

LNG Tanker” means an ocean-going vessel suitable for the transportation of LNG which conforms to the specifications set forth in Exhibit A.

Loading Rate Test” has the meaning set forth in Exhibit R.

Losses” means any and all losses, liabilities, damages, costs, charges, expenses, fines, interest, awards and penalties, which are the result of or arise in connection with any actions, suits, claims, demands, causes of action, litigation, lawsuits, administrative proceedings or administrative investigations.

LPS1” means the systems and sub-systems comprising a portion of the Facility and including the first [***] Blocks that are collectively identified as such in Exhibit A.

LPS1 Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.1 as liquidated damages for the delay in the achievement of LNG Production System Substantial Completion of LPS1.

LPS1 Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1.

LPS1 Substantial Completion Date” means the date on which LNG Production System Substantial Completion is achieved for LPS1.

LPS1 Substantial Completion Deadline” means the date so identified on Exhibit D.

LPS2” means the systems and sub-systems comprising a portion of the Facility and including [***] Blocks that are collectively identified as such in Exhibit A.

LPS2 Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.2 as liquidated damages for the delay in the achievement of LNG Production System Substantial Completion of LPS2.

LPS2 Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(b).

LPS2 Substantial Completion Date” means the date on which LNG Production System Substantial Completion is achieved for LPS2.

LPS2 Substantial Completion Deadline” means the date so identified on Exhibit D.

LPS3” means the systems and sub-systems comprising a portion of the Facility and including [***] Blocks that are collectively identified as such in Exhibit A.

LPS3 Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.3 as liquidated damages for the delay in the achievement of LNG Production System Substantial Completion of LPS3.

 

13


Execution Version

 

LPS3 Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(b).

“LPS3 Substantial Completion Date” means the date on which LNG Production System Substantial Completion is achieved for LPS3.

LPS3 Substantial Completion Deadline” means the date so identified on Exhibit D.

LPS4” means the systems and sub-systems comprising a portion of the Facility and including the final [***] Blocks that are collectively identified as such in Exhibit A.

LPS4 Schedule Delay Liquidated Damages” means the amounts to be paid by Contractor to Owner in accordance with the provisions of Section 22.2.4 as liquidated damages for the delay in the achievement of LNG Production System Substantial Completion of LPS4.

LPS4 Schedule Delay Liquidated Damages Cap” has the meaning set forth in Section 22.3.1(d).

“LPS4 Substantial Completion Date” means the date on which LNG Production System Substantial Completion is achieved for LPS4.

LPS4 Substantial Completion Deadline” means the date so identified on Exhibit D.

LTS PO” means that certain Purchase Order Contract for the Sale of the Liquefaction Train System, dated as of April 7, 2023, between Owner and BH.

Major Subcontract” means (a) any Subcontract providing services or Materials for the Work having an aggregate value in excess of [***], or (b) multiple Subcontracts with the same Subcontractor (including any Subcontractor that is an Affiliate of Contractor) providing services or Materials for the Work having an aggregate value in excess of [***].

Major Subcontractor” means each Subcontractor that is party to a Major Subcontract.

Make Good Commencement Date” has the meaning set forth in Section 15.3.4.

Margin Milestone” means a milestone identified as a Margin Milestone in Exhibit D.

Margin Percentage” means, initially, [***], as such percentage may be adjusted pursuant to this Agreement.

Marine Works” means the scope described in Section 3.5 of Exhibit A.

Material Change” means any proposed Change Order or other amendment, supplement or modification to this Agreement which, directly or indirectly, (a) delays, extends or changes an Applicable Deadline, (b) modifies the requirements for successfully passing any Demonstration Tests or Performance Tests or the manner in which any Demonstration Tests, or Performance Tests are performed or the results thereof are measured, (c) diminishes the scope or duration of any

 

14


Execution Version

 

Contractor warranty, (d) alters the amount, timing or manner of payment of any Contractor liquidated damages, (e) causes the Work (or any portion thereof) to materially deviate from the requirements set forth in Exhibit A, (f) increases the Target Price by more than [***] for an individual change or, when aggregated with all other changes previously effected, causes the Target Price to increase by an amount that is more than an [***] or (g) otherwise materially diminishes, lessens or waives any liability or obligation of Contractor under this Agreement or any right or benefit of Owner hereunder. The term “Material Change” is a term distinct and separate from references herein to “material adverse change,” and shall in no way be construed or applied to define the word “material” or “materially” when used herein.

Materials” means those equipment, materials, supplies, apparatus, machinery, parts, tools (including any special tools), components, instruments, appliances, systems, construction and testing-related spare parts and appurtenances thereto (a) required for prudent design, engineering, procurement, construction, installation, Pre-Commissioning, Commissioning, testing, delivery and operation, maintenance and repair of the Work and for the installation, Pre-Commissioning at the Job Site, Commissioning, testing, and operation of the Facility in accordance with Owner Standards and supplied under the terms of this Agreement, (b) described in or required as part of the Work by Exhibit A, excluding, in each case, the Owner Furnished Equipment and Materials.

Mixed Refrigerant” means a mixture of gases or liquids, including ethylene, propane, i-pentane, nitrogen and other gases as may be required to operate a Liquefaction Train.

MMBtu” means one million British Thermal Units.

MMSCFD” means Million Standard Cubic Foot per Day.

MOF Facility” means each site located in the vicinity of the Job Site that is designated by Owner to be utilized by Contractor and/or its Subcontractors for the positioning, storage and/or transshipment of certain equipment and materials necessary for the performance of the Work.

Month N means the calendar month during which the Notice to Proceed Date occurs or a subsequent month, as applicable, during which Work is performed.

Month N+2” has the meaning set forth in Section 6.3.1.

Monthly Progress Report” has the meaning set forth in Section 13.3.

MTPA” means million Tonnes of LNG per annum.

MW” means one (1) megawatt or one million (1,000,000) watts.

Non-Reimbursable Costs” has the meaning set forth in Exhibit B-1.

Notice” means a written communication from one Party to another Party required or permitted by this Agreement, conforming to the requirements of Article 38.

Notice of Contract” has the meaning set forth in Section 3.8.56.

 

15


Execution Version

 

Notice of Dispute” has the meaning set forth in Section 36.1.1.

Notice to Proceed” has the meaning set forth in Section 4.1.1.

Notice to Proceed Date” has the meaning set forth in Section 4.1.1.

Open Cost Items” has the meaning set forth in Section 6.1.3.

“Owner” has the meaning set forth in the introductory paragraph hereof, and includes its legal successors and those permitted assigns as may be designated by Owner, in writing, pursuant to the terms of this Agreement.

“Owner Caused Delay” means any delay in the performance and completion of the Work by the Applicable Deadline that is directly and demonstrably caused by an act, omission or failure by Owner, Owner Contractors or any party for whom Owner is responsible hereunder, to perform its obligations hereunder, including as a result of: (i) the failure of Owner to obtain a Permit that Owner is required to obtain hereunder; (ii) the failure of the Owner Furnished Equipment and Materials to perform in accordance with the requirements of the Owner Contract(s) (including as a result of defects or deficiencies in the Owner Furnished Equipment and Materials) pursuant to which such Owner Furnished Equipment and Materials were purchased by Owner; (iii) the failure by Owner to perform the Owner Scope of Work, including the supply of the Owner Furnished Equipment and Materials, on the agreed schedule therefor; (iv) the failure of BH to declare “Ready for Test” (as that term is defined in the LTS PO) in relation to the liquefaction trains comprising any LNG Production System within [***] days of Contractor achieving LNG Production System RFSU in respect of such LNG Production System, as described in Section 18.2.1 (a “BH Testing Delay”); or (v) the failure of an Owner Contractor to timely perform its obligations under its respective Owner Contract(s); provided, however, that, notwithstanding the foregoing, “Owner Caused Delay” does not include: (a) any act or omission (except as to item (vi) above) that is permitted under, and is taken or caused in accordance with, the terms of this Agreement; (b) any act or omission of Owner acting under or in accordance with any written instructions from Contractor or the Contractor’s Representative; or (c) any act, omission or failure by Owner, Owner Contractors or any party for whom Owner is responsible that does not actually, demonstrably and adversely affect the Critical Path (except with respect to (iv) above, in which case Contractor is entitled to a day for day extension as described in Section 12.1.1).

Owner Contractor” means any party to an Owner Contract (other than Owner), and their subcontractors of any tier.

Owner Contracts means:

(1) the Construction Agreement relating to the Marine Works to be entered into between Owner and TBD;

(2) the Construction Agreement relating to the Storm Surge Wall to be entered into between Owner and TBD;

(3) the LTS PO;

 

16


Execution Version

 

(4) the PIS PO;

(5) the LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 1) to be entered into by and between CB&I LLC and Owner;

(6) the PTS PO; and

(7) the Pipeline and Gas Gate Station PO.

Owner Designees” means the Independent Engineer, Owner’s Representative, any Affiliate of Owner so designated in writing by Owner and all other consultants, contractors, agents or representatives Owner or its Affiliate employs or appoints in connection with the performance of Owner’s rights and obligations under this Agreement.

Owner Furnished Equipment and Materials” means the equipment, materials or components of the Facility that are to be furnished or procured by Owner or the Owner Contractors under the Owner Contracts as part of the Owner Scope of Work.

Owner Indemnitees” means Owner, Owner’s Representatives, the Lenders, the Independent Engineer and all Affiliates, officers, directors, employees and agents thereof.

Owner Protocols” means the protocols for the Contractor’s operation of the Facility during the period commencing on the LNG Production System Substantial Completion Date for the first LNG Production System to achieve LNG Production System Substantial Completion and ending on the Facility Substantial Completion Date, as described in Exhibit T.

Owner Scope of Work” means the services and other activities performed by or on behalf of Owner that are specifically identified as the “Owner Scope of Work” in Exhibit A.

Owner Standards” unless otherwise specified in Exhibit A, means those sound and prudent practices, methods, specifications or standards of design, engineering, construction, performance, safety, workmanship, equipment and components prudently and generally engaged in or observed by the majority of the professional engineering and construction contractors in the LNG and electric power industry in the United States of America for similar types of LNG export and liquefaction facilities and power generation facilities that at a particular time, in the exercise of reasonable judgment, would have been expected to accomplish the desired result in a manner consistent with applicable Laws, Applicable Codes and Standards, Permits, reliability, health and safety, environmental protection and local conditions and to maximize the LNG production of the Facility, but such standards are not limited to the best or optimum practice or method to the exclusion of all others. Without limiting the foregoing, the Facility or any portion thereof or any technical specifications shall not be required to meet any specifications less or more stringent than the specifications set forth herein. Owner Standards are not intended to be limited to the optimum practices, methods, or standards to the exclusion of all others, but rather to be a spectrum of reasonable and prudent practices, methods, and standards employed by firms in the engineering and construction industry familiar with building comparable facilities on the Gulf Coast of the United States of America.

 

17


Execution Version

 

Owner’s Representative” means Owner’s employee or representative designated by Owner pursuant to Section 3.7.3.

Parties” means Owner and Contractor collectively, and “Party” means Owner or Contractor, individually, as applicable.

Payment Bond” means the Payment Bond described in Section 9.2.3.

Performance and Payment Bonds” has the meaning set forth in Section 9.2.1.

Performance Bond” means the Performance Bond described in Section 9.2.2.

Performance Security” means the security provided by Contractor to Owner in the form of the (a) Performance and Payment Bonds, and (b) the Contractor Guarantee.

Performance Tests” has the meaning set forth in Exhibit R.

Permit” means any authorization, consent, approval, license, ruling, permit, exemption, filing, variance, order, judgment, decree, publication, condition, notice to, declaration or registration of or with or regulation by or of any Government Authority relating to the acquisition, ownership, occupation, construction, Pre-Commissioning, Commissioning, testing, operation or maintenance of the Facility.

Permitted Liens” means materialmen’s, mechanics’, workers’, repairmen’s, employees’ or other similar liens filed by a Subcontractor arising in the ordinary course of business for amounts not yet due or for amounts being contested in good faith, so long as, in the case of any such contest, (a) Contractor shall have posted or provided to Owner a letter of credit, bond (in form and substance acceptable to Owner) or other security reasonably satisfactory to Owner and the Independent Engineer in an amount equal to such contested lien, and (b) such proceedings in Owner’s reasonable judgment shall not involve any danger of the sale, forfeiture or loss of any part of the Facility, title thereto or any interest therein and shall not interfere with the timely completion, use or disposition of the Facility.

Person” means an individual, a corporation, a limited liability company, an unincorporated organization, a partnership, a joint venture, an association, a trust or any other entity or organization, including a Government Authority.

Pipeline and Gas Gate Station PO” means the Construction Agreement for the CP Express Pipeline.

Pipeline Contractor” means the Person engaged to engineer, procure and construct the CP Express Pipeline.

Pipeline Tie Point(s)” means the point(s) where the systems of the Facility are interconnected with the CP Express Pipeline, as more specifically described in Exhibit A.

PIS PO” means the Purchase Order Contract for the Sale of the Power Island System, to be entered into between Owner and BH.

 

18


Execution Version

 

Power Island System” means the facilities described in Section 3.7 of Exhibit A.

Power Plant” means (i) five (5) [***] Gas Turbines and associated generators, two (2) [***] steam turbines and associated generators, five (5) HRSG’s [***], two (2) air-cooled condensers, (ii) three (3) [***] Gas Turbines and associated generators relating to LPS4; and (iii) the associated pumps, piping, valves, instrumentation, electrical systems, and control systems, including any required auxiliary or ancillary equipment, as more specifically described in Exhibit A.

Pre-Commissioning” means the checks, tests and calibrations set forth in Exhibit P and required to be performed as part of the Work prior to performing the Commissioning of an LNG Production System, including all applicable safety related and utility components being placed in service and made operational, completion of all function testing/static commissioning activities that do not involve the introduction of hydrocarbons into systems, such as loop checks, operating control and emergency actuated valves, panel function tests, energizing electrical equipment and running motors without loads, all carried out on a single discipline basis, typically by system/subsystem, and the completion of all ‘A’ and ‘B’ inspection and test records and agreed punch lists.

Pre-Existing Hazardous Substance” means a Hazardous Substance that existed or was present on, at or under the Job Site on or before the Notice to Proceed Date.

Pre-Treatment System” means an acid gas treating, dehydration and regeneration system, and heavy hydrocarbon removal system, as further described in Exhibit A.

Primary Milestone” means a Schedule Milestone identified as a Primary Milestone on Appendix 2 of Exhibit D.

Primary Milestone Bonus” means a bonus payment in an amount equal to [***], as such amount may be adjusted pursuant to Sections 7.2.2 and 7.2.3.

Project Schedule” means the schedule for the performance of the Work developed, delivered and maintained in accordance with Exhibits D and E.

PTS PO” means the Purchase Order Contract for the Sale of the Pre-Treatment System, to be entered into between Owner and TBD.

Punch List Items” means those minor items of the Work identified by Owner or Contractor as requiring completion or correction prior to Final Completion, which items do not affect the performance or safe and continuous operation of an LNG Production System or the Facility.

Qualified Surety” means a U.S. bank, insurance company, or other financial institution which is rated at least “A” by Standard & Poor’s Ratings Group, Inc. (or a comparable rating from another internationally recognized ratings agency).

Quality Management Plan” has the meaning set forth in Section 10.1.

 

19


Execution Version

 

Ready for Commissioning Certificate” means the certificate provided to Owner by Contractor, after LNG Production System Mechanical Completion and completion of Pre-Commissioning of an LNG Production System, certifying that such LNG Production System is ready for Commissioning.

Reimbursable Costs” means Direct Costs that are reimbursable to Contractor, as described in Exhibit B-1.

Reimbursable Work” means the Work, excluding the Corrective Work.

Release” means any emission, spill, seepage, leak, escape, leaching, discharge, injection, pumping, pouring, emptying, dumping, disposal, migration, or release of Hazardous Substances from any source into or upon the indoor or outdoor environment.

Relied Upon Information” has the meaning set forth in Exhibit M.

Representatives” means, with respect to a Party, such Party’s Affiliates, directors, officers, and employees.

Request for Payment” means the Contractor’s monthly submission to Owner of all documentation and materials required by Section 6.2 requesting payment, which request for payment shall be in the form provided in Exhibit F-7.

Schedule Bonus” means an Interim Milestone Bonus, a Primary Milestone Bonus or a Super Primary Milestone Bonus, as applicable.

Schedule Bonus Cap” means [***].

Schedule Delay Liquidated Damages” means the LPS1 Schedule Delay Liquidated Damages, the LPS2 Schedule Delay Liquidated Damages, the LPS3 Schedule Delay Liquidated Damages, the LPS4 Schedule Delay Liquidated Damages and the Facility Schedule Delay Liquidated Damages.

Schedule Milestone” means an event to be achieved by Contractor for payment of a Schedule Bonus pursuant to and in accordance with Article 7, as described on Appendix 2 of Exhibit D.

SDN” has the meaning set forth in Section 40.1.1.

“Senior Supervisory Personnel” means Contractor’s project director, project engineering manager, project construction manager and other Contractor personnel identified in Exhibit K.

Serial Defect” has the meaning set forth in Section 20.2.6.

Severe Injury” means an injury or accident that requires, or is reasonably likely to require, a formal admission to a hospital or clinic for care or treatment, excluding treatment solely in an urgent care center.

 

20


Execution Version

 

Shipping Information” has the meaning set forth in Section 3.10.

Spare Parts” has the meaning set forth in Section 3.9.1.

Storm Surge Wall” means the facilities described in Section 3.6 of Exhibit A.

Subcontract” means an agreement (including a purchase order) (a) by Contractor with a Subcontractor for the supply of any equipment or materials or the performance of any portion of the Work or (b) by a Subcontractor with a lower tier of Subcontractor for the supply of any equipment or materials or the performance of any portion of the Work.

Subcontractor” means any Person (other than Contractor) that performs any portion of the Work, whether hired directly by Contractor, or by a Person hired by Contractor and including every tier of Subcontractor, sub-subcontractors, vendors, suppliers and so forth.

Super Primary Milestone” means a Schedule Milestone identified as a Super Primary Milestone on Appendix 2 of Exhibit D.

Super Primary Milestone Bonus” means a bonus payment in an amount equal to [***], as such amount may be adjusted pursuant to Sections 7.3.2 and 7.3.3.

Surplus Construction Materials” has the meaning set forth in Section 3.8.15.

Suspension Notice” means a notice of suspension provided by Owner to Contractor in accordance with Section 17.1.1 or 17.1.2.

Suspension Period” has the meaning set forth in Section 17.1.1.

System Turnover Package” means those binders defined by the individual system process and instrument diagrams (P&ID) and electrical single line diagrams in which Contractor compiles all relevant quality assurance and quality control test results which show that the system and its components were installed and tested in full conformance with the design drawings, vendor requirements, Owner Standards and this Agreement.

Tank One” means the LNG Storage Tank so identified on the plot plan provided in Exhibit A.

Tank Two” means the LNG Storage Tank so identified on the plot plan provided in Exhibit A.

Target Price” has the meaning set forth in Section 6.1.

Tax” means any present or future tax (including any stamp duty, income, payroll, sales, use, value added, consumption or goods and services tax), tariff, levy, impost, duty, charge, fee, deduction or withholding of whatever nature, including any such income tax, payroll tax, value added tax, sales tax, stamp tax, customs duty, import duty, export duty, withholding tax, excise tax, property tax, registration fee or license, water tax, sanitary tax, lighting tax or environmental,

 

21


Execution Version

 

energy or fuel tax, which is levied, collected, assessed or imposed by a Government Authority at any time, and any interest, penalty, charge, fee or other amount imposed, collected, withheld, assessed or made on or in respect of any of the above.

Tax Costs” means any sales tax or sales and use tax levied by any U.S. state or any political subdivision thereof that is incurred by Contractor in the performance of the Work.

Third Party” means any party other than an Owner Indemnitee, a Contractor Indemnitee, an Owner Contractor or an Owner Contractors’ subcontractors.

Tonne” means metric ton and is defined as 2,204.6 lbs.

Total Cost Exclusions means for the purposes of Section 8.1.2: (i) Taxes, if paid by Contractor which will then be reimbursed by Owner, unless such Taxes constitute Non-Reimbursable Costs; (ii) costs incurred by Contractor with respect to Owner Furnished Equipment and Materials described in Section 1.1.2(O) of Exhibit B-1; (iii) uninsured losses and deductibles arising under the Construction and Erection All Risk Insurance Policy, Owner Controlled Insurance Program for Commercial General Liability Policy, marine cargo, and any permanent property insurance policy, each procured by Owner; (iv) Direct Costs paid to or paid by Contractor for Work subject to a claim against the Builder’s Risk Insurance Policy, Owner Controlled Insurance Program for Commercial General Liability Policy Marine Cargo, or Permanent Property Insurance policies; and (v) any other cost expressed to be excluded from the calculation of Total Costs hereunder; provided that, in the case of Defects or Deficiencies, the Direct Costs paid to Contractor or costs incurred by Owner in order to correct the Defects or Deficiencies in accordance with Section 20.5 shall be included in the calculation of “Total Costs”.

Total Costs” has the meaning set forth in Section 8.1.2.

Treated Gas” means natural gas that has been treated (through removal of compounds or otherwise) for quality to make it suitable for feed into a Liquefaction Train.

U.S.” has the meaning set forth in Section 40.3.1.

UOP” means UOP LLC or any of its Affiliates.

Warranties” has the meaning set forth in Section 20.2.7.

Warranty Period” means the period that commences on the relevant LNG Production System Substantial Completion Date and ends [***] after the Facility Substantial Completion Date, subject to any extension thereof pursuant to Sections 20.2.6 and 20.4.

Work” means all acts or actions required to be performed by Contractor and its Subcontractors under this Agreement, or necessary for Contractor to complete its obligations hereunder, including the integration and installation of Owner Furnished Equipment and Materials and the design and engineering (including verification of the integration design for purpose of confirming the Facility Performance Tests requirements and undertaking of a debottlenecking or plant integration constraint study of the Facility for the purpose of maximizing the performance of the Facility, and such other studies, as applicable, described in Exhibit A or as Owner may

 

22


Execution Version

 

reasonably request, and implementing the recommendations of such studies), procurement, manufacturing, preservation, packing and transportation, construction, training, erection, testing, Pre-Commissioning, Commissioning, start-up, operation, and guaranteeing of the Facility in accordance with Article 15, whether at the Job Site or elsewhere, until Final Completion and satisfaction of Contractor’s warranty obligations during the Warranty Period, as more fully described in Exhibit A and this Agreement, and such other acts as may be necessary to provide Owner with a fully operational and integrated Facility which successfully passes the Performance Tests, meets or exceeds the Owner Standards and otherwise satisfies the conditions set forth herein. The term “Work” shall also include providing security of the Job Site and construction management services relating to the scheduling and coordination of the work and services performed by the Owner Contractors under the Owner Contracts and the administration of the performance by each Owner Contractor of its obligations of the relevant Owner Contract(s). Notwithstanding the foregoing, the term “Work” shall not include: (i) the supply or performance (except as it relates to installation or integration) of the Owner Furnished Equipment and Materials; (ii) the performance of the Owner Scope of Work; or (iii) any other obligation of Owner specifically described herein.

 

2.

AGREEMENT; EXHIBITS; CONFLICTS.

 

2.1

LANGUAGE OF AGREEMENT.

This Agreement and all documentation to be supplied hereunder (including the operation and maintenance manuals which Contractor provides to Owner pursuant to Section 3.8.6 as well as all warranties provided hereunder) shall be in the English language. All dimensions and properties set forth herein, any Exhibit hereto and any Drawings and Specifications shall be specified in English or U.S. customary units unless otherwise approved by Owner or agreed with Owner as a normal practice with respect to LNG liquefaction facility or power plant design. Words not otherwise defined herein that have well-known and generally accepted technical or trade meanings are used herein in accordance with such recognized meanings in the United States of America.

 

2.2

PRECEDENCE OF AGREEMENT.

2.2.1 Each Party shall promptly notify the other in writing of any discovered conflict or inconsistency among any of the Exhibits or between any Exhibit and the body of this Agreement. In the event of any conflict between provisions of Sections of this Agreement, Drawings and Specifications and Exhibits, the following order of precedence for construction and interpretation shall apply unless the Parties otherwise agree:

(a) amendments, addenda or other modifications to this Agreement (including Change Orders) duly signed and issued after the Effective Date, with those of a later date having precedence over those of an earlier date;

(b) Sections of this Agreement;

(c) Exhibit R – Demonstration Tests and Performance Tests;

(d) Exhibit C – Contractor Rates;

 

23


Execution Version

 

(e) Exhibit B – Compensation;

(f) Exhibit D – Form of Project Schedule and Milestones;

(g) Exhibit A – Scope of Work; Applicable Codes and Standards;

(h) the remaining Exhibits to this Agreement; and

(i) Drawings and Specifications.

2.2.2 Subject to Section 2.2.1, in the event of a conflict among or within any of the levels set forth in Section 2.2.1, the more stringent provision shall prevail. Notwithstanding the above, the provisions of this Agreement, including all Exhibits, shall be wherever possible construed as complementary rather than conflicting. Silence regarding a matter shall not constitute a conflict with another component of the Agreement that specifically addresses such matter.

 

2.3

INTERPRETATION.

Unless the context otherwise requires:

2.3.1 Words singular and plural in number will be deemed to include the other and pronouns having a masculine or feminine gender will be deemed to include the other;

2.3.2 In respect of general oversight of the Work, review of any Drawings and Specifications, access to the Job Site and the Work and all other similar rights of Owner, the term Owner shall be deemed to include Owner’s Representative and its designated staff;

2.3.3 Any reference to this Agreement or any other contract or agreement entered into by Owner in respect of the Facility means such agreement and all schedules, exhibits and attachments thereto as may be amended, supplemented or otherwise modified and in effect from time to time, and shall include a reference to any document which amends, modifies or supplements it, or is entered into, made or given pursuant to or in accordance with its terms;

2.3.4 The terms “hereof,” “herein,” “hereby,” “hereto”, “hereunder” and similar words refer to this entire Agreement and not any particular Section, subsection or other subdivision of, or Exhibit, appendix or schedule to, this Agreement;

2.3.5 The terms “include” and “including” shall be construed as being at all times followed by the words “without limitation” or “but not limited to” unless the context specifically indicates otherwise;

2.3.6 The words “as more fully described in” or words and phrases of similar meaning are not intended to be, nor should be construed to limit in any way, the obligations of Contractor to provide Owner with a fully operational Facility pursuant to the terms hereof;

2.3.7 References to “Article,” “Section” or “Exhibit” are to this Agreement unless specified otherwise;

 

24


Execution Version

 

2.3.8 References to Contractor’s personnel include employees of its Affiliate assigned to the performance of the Work;

2.3.9 References to any law, statute, rule, regulation, notification or statutory provision (including Laws and Permits) shall be construed as a reference to the same as it may have been, or may from time to time be, amended, modified or re-enacted;

2.3.10 References to any Person shall be construed as a reference to such Person’s successors and permitted assigns; and

2.3.11 The word “or” will have the inclusive meaning represented by the phrase “and/or”.

 

2.4

NEGOTIATION AND DOCUMENTATION OF THIS AGREEMENT.

Each of the Parties acknowledges and agrees that it has had the opportunity to have its legal counsel review this Agreement and participate in the joint negotiation and documentation of this Agreement, and that it is fully familiar with each of the provisions of this Agreement and the effect thereof. Accordingly, each Party irrevocably waives the benefit of any rule of construction that disfavors the drafting party and any defense related thereto.

 

3.

GENERAL PROVISIONS.

 

3.1

WORK TO BE PERFORMED.

3.1.1 Owner hereby engages and is relying upon Contractor to perform the Work in accordance with Exhibit A and the other requirements of this Agreement, and Contractor acknowledges such reliance and accepts such engagement. Owner and Contractor agree, despite anything to the contrary contained herein, that Contractor’s obligation under this Agreement is to complete the Work so that the Facility successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the other provisions of this Agreement, including achieving Facility Mechanical Completion, Facility Substantial Completion, and Final Completion within the time and for the purpose designated herein, and to do and furnish everything necessary in connection therewith.

3.1.2 Prior to the execution of this Agreement, Contractor performed engineering, cost estimating and related services and developed, provided or verified all of the information that forms the scope of Work set forth in Exhibit A for the purpose of verifying that such information is adequate for, and Contractor represents and warrants to Owner that the scope of Work set forth in Exhibit A includes all the necessary obligations, including integration, as applicable, that are required to be performed by Contractor and Owner in order for, the Facility to operate in accordance with the terms of this Agreement and to satisfy the Applicable Codes and Standards, applicable Laws, Owner Standards and Permits and successfully pass the Performance Tests and meet or exceed the requirements set forth in Exhibit A. Items need not be specifically listed herein or in Exhibit A in order to be deemed to be items within the scope of the Work. It is understood that Contractor is better qualified to list exclusions than Owner is to list inclusions. Therefore, except for the supply of Owner Furnished Equipment and Materials and performance of the Owner Scope of Work, any item indicated herein, inferable therefrom, incidental thereto or required in accordance with any Law, Permits or Applicable Codes and Standards is to be considered as part

 

25


Execution Version

 

of the Work. In addition, the Work includes all that should be included and all that would be customarily included within the general scope of the Work in order to complete the Facility (excluding the supply of Owner Furnished Equipment and Materials and performance of the Owner Scope of Work) according to the requirements of this Agreement, including Applicable Codes and Standards, applicable Laws, the requirements for the Performance Tests and the Permits. As a result, Contractor hereby waives any and all claims for an increase in the Target Price or an extension of any Applicable Deadline based, in whole or in part, upon an assertion that Contractor’s scope of Work in Exhibit A and as otherwise provided in the Exhibits was insufficient and did not include a certain license, technical assistance, engineering, assembly, construction, service, labor, material, equipment, operation or management beyond the scope of the Work when such license, technical assistance, engineering, assembly, construction, service, labor, material, equipment, operation or management is indicated in Exhibit A, this Agreement or any other Exhibit, the Drawings and Specifications or other instruments of service prepared by Contractor or a Subcontractor in connection with this Agreement reasonably inferable therefrom, incidental thereto, required in accordance with any Applicable Codes and Standards, applicable Law, Permits or otherwise necessary in order to complete the Facility in accordance with and subject to the requirements of this Agreement.

3.1.3 Time is of the essence with respect to Contractor’s achievement of each Applicable Deadline (other than the Final Completion Deadline).

 

3.2

GENERAL OVERSIGHT AND ACCESS.

3.2.1 Owner and the Owner Designees shall at all times have access to the Job Site and the Work wherever it is in preparation and progress and Contractor shall provide reasonable facilities for such access. Owner and the Owner Designees shall comply with the Contractor’s reasonable safety and access procedures. Each of Owner and the Owner Designees may (a) make inquiries of Contractor and visit the Job Site and Contractor’s work facilities, and/or (b) maintain staff on the Job Site, in each case, to (i) familiarize itself with the progress and quality of the Work, (ii) determine if the Work is proceeding in accordance with this Agreement, and (iii) witness and/or participate in Pre-Commissioning and Commissioning and any tests (including the Performance Tests) and inspections of the Materials and any other component of the Facility.

3.2.2 Subject to the limitations of the immediately following sentence, Owner Contractors and the Pipeline Contractor shall at all times have access to the entire Job Site and the Work wherever it is in preparation and progress, and Contractor shall provide reasonable facilities for such access. Owner Contractors and the Pipeline Contractor shall comply with the Contractor’s reasonable safety and access procedures for access to and when present on the Job Site.

3.3 JOB SITE CONDITIONS.

Except as otherwise provided herein, Contractor has had sufficient opportunity to review (a) information provided to it by Owner as set forth in Exhibit M and Exhibit N, and (b) the information it has developed on its own (excluding sub-surface testing), and it is sufficiently informed about the Job Site and surrounding locations, including all visible surface conditions, to the full extent it deems necessary for the performance of the Work and is familiar with and has satisfied itself with respect to (i) the nature and location of the Work, and (ii) the general and local

 

26


Execution Version

 

conditions with respect to (A) environment, (B) transportation (including to the Job Site and within the Job Site), (C) access, (D) the use, handling, storage and disposal of Hazardous Substances and other wastes brought to the Job Site by Contractor or any Subcontractor, (E) the use, handling and storage of Materials, (F) the availability and quality of temporary construction electric power, (G) the availability and condition of roads, climatic conditions and seasons (except to the extent any such climatic conditions constitutes a Force Majeure Event), (H) physical and environmental conditions at the Job Site and the surrounding area as a whole, (I) topography and ground surface conditions, (J) nature and quantity of surface materials to be encountered, (K) location of underground utilities existing prior to the Effective Date which were (1) disclosed to Contractor by Owner in writing in Exhibit M or Exhibit N, or (2) identified by Contractor (or any Affiliate thereof), (L) construction equipment, and other equipment, supplies and facilities needed prior to and during performance of Contractor’s obligations under this Agreement, and (M) the availability and quality of workers, laborers and Subcontractors (the foregoing, collectively, the “Job Site Conditions”). Contractor expressly waives any claims for any increase in the Target Price or adjustment to the Project Schedule in connection with the Job Site Conditions.

 

3.4

OWNER NOT RESPONSIBLE FOR ACTS OF CONTRACTOR; CONTRACTOR NOT RESPONSIBLE FOR OWNER SCOPE OF WORK.

3.4.1 Other than with respect to means, methods, sequences, procedures and techniques of construction (for which Contractor shall have sole responsibility), Contractor will comply with instructions and requests of Owner or Owner’s Representative which are consistent with the Work and the requirements set forth in Exhibit A; provided that Contractor will comply with technical instructions and requests of BH and UOP in connection with the unloading, transport, installation, connection, start-up, commissioning and operation of any Owner Furnished Equipment and Materials supplied by BH and UOP. Owner will not be responsible for construction or manufacturing means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, and Owner will not be responsible for Contractor’s failure to carry out the Work in accordance with this Agreement. Owner will not be responsible for the acts or omissions of Contractor, any Subcontractor, or any of their agents or employees, or any other Persons performing any of the Work on behalf of Contractor or any Subcontractor. No inspection, or failure to inspect, by Owner, Owner’s Representative or the Independent Engineer shall be a waiver of Contractor’s obligations, or be construed as approval or acceptance of the Work or any part thereof.

3.4.2 Except and solely to the extent set forth in Exhibit A, Contractor will not be responsible for construction or manufacturing means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Owner Scope of Work, and Contractor will not be responsible for Owner’s or any Owner Contractor’s failure to carry out the Owner Scope of Work, the supply or performance of the Owner Furnished Equipment and Materials (except to the extent expressly identified as part of the Work). Contractor will not be responsible for the acts or omissions of Owner, any Owner Contractor, or any of their agents or employees, or any other Persons performing any of the Owner Scope of Work.

 

27


Execution Version

 

3.5

EFFECT OF AND TIME FOR OWNER REVIEW OF DOCUMENTS.

Inspection, review or comment by Owner or the Independent Engineer (or the failure to do so) with respect to any Subcontract, Drawings and Specifications or other documents, or any other Work or services performed by Contractor or any Subcontractor, shall not in any way affect or reduce any of the Contractor’s obligations to complete the Work so that the Facility successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the other provisions of this Agreement or in any way affect the Target Price. Contractor shall prepare Drawings and Specifications and submit them to Owner and the Independent Engineer at least thirty (30) days before the date on which the Work described in them is to be performed. Upon the written request of the Owner, Contractor shall provide to the Owner any information reasonably requested in connection with the Drawings and Specifications. Owner may, but is not obligated to, have the Independent Engineer review the Drawings and Specifications submitted by Contractor. Contractor shall discuss and answer any inquiries concerning the Drawings and Specifications with Owner or the Independent Engineer. Owner may reject or amend the Drawings and Specifications that are not in accordance with the requirements set forth in Exhibit A, Owner Standards and the other provisions of this Agreement. Owner and Independent Engineer shall review and comment on Drawings and Specifications submitted for review within twenty-one (21) days of their submittal. In the event that Owner and/or Independent Engineer do not reject or provide comments within twenty-one (21) days of their submittal, then Contractor shall be permitted to proceed with the Work that relates to such submittal until such time as Owner and/or Independent Engineer reject or provide comments, and such late rejection or comments may be considered an Owner Caused Delay (so long as it satisfies the definition thereof) as measured from the twenty-first day after receipt of the submittal unless the rejected submittal did not comply with the requirements of the Agreement.

 

3.6

CLAIMS UPON FAILURE OF MATERIAL.

In accepting the Work performed and Materials supplied, assembled or installed by Contractor, Owner assumes no responsibility for injury or claims resulting from (a) failure of such Work and Materials to comply with applicable Laws, Permits, safety requirements, Applicable Codes and Standards and Owner Standards, (b) Contractor’s failure to unload, transport, integrate, install, connect, start-up, commission or operate all Owner Furnished Equipment and Materials in accordance with applicable Laws, Permits, safety requirements, Applicable Codes and Standards, Owner Standards, Owner instructions and Owner Contractor instructions (provided that the Owner Standards, Owner instructions and Owner Contractor instructions are consistent with applicable Laws, Permits, safety requirements, and Applicable Codes and Standards), (c) Defects or Deficiencies (other than Owner’s obligation hereunder to pay the Reimbursable Costs, Contractor’s G&A and Contractor’s Margin associated with Defects or Deficiencies) or (d) Corrective Work. Contractor’s performance of the Work shall include the provision of all necessary permanent safety devices in accordance with the terms hereof, Owner Standards and as required by Government Authority or applicable safety codes.

 

3.7

RESPONSIBILITIES OF OWNER.

Without limiting the requirements of any other provision of this Agreement, Owner shall:

 

28


Execution Version

 

3.7.1 furnish nonexclusive access to the Job Site to Contractor from and after the time of the issuance of the Notice to Proceed or, if expressly authorized in the Limited Notice to Proceed, the time of issuance of the Limited Notice to Proceed;

3.7.2 provide legal rights for ingress to and egress from the Job Site for Contractor and its Subcontractors for the performance of the Work and for the Owner Contractors and the Pipeline Contractor, consistent with Owner’s property rights with respect to the Job Site. During the progress of the Work, it will be necessary for Owner and Owner Contractors to work in or about the Job Site. In accordance with Section 3.2.2, Contractor shall afford such Owner Contractors reasonable access through and across the Job Site so as to not materially adversely interfere with or impede the progress and execution of work performed by such Owner Contractors in or about the Job Site. Contractor shall exercise good faith cooperation with the Owner Contractors and the Pipeline Contractor;

3.7.3 designate a single individual as Owner’s Representative to act as a single point of contact for Contractor, Owner Contractors and the Pipeline Contractor with respect to the prosecution of the Work. Any proposal, inspection, examination, testing, consent, approval or similar act by Owner’s Representative (including absence of disapproval) shall not relieve Contractor from any responsibility, including responsibility for its errors, omissions, discrepancies and non-compliance with the terms of this Agreement. Owner shall have the right to change the Owner’s Representative and/or modify his/her scope of responsibilities upon reasonable notice to Contractor. The Owner’s Representative shall be available at the Job Site and elsewhere, when reasonably required, at all reasonable times for consultation and, if absent, shall designate a suitable alternate to act as Owner’s Representative during such absence;

3.7.4 furnish personnel in accordance with Exhibit G for training, testing, operation and maintenance of the Facility, which personnel shall possess experience and education qualifications which in Owner’s determination are appropriate to permit achievement of the training objective;

3.7.5 with Contractor’s assistance, obtain or cause to be obtained in a timely manner the Permits listed in Exhibit L that are identified as Owner Permits (excluding for the avoidance of doubt the Permits set forth in Exhibit L that are identified as Contractor Permits) and any other Permit required under applicable Law to be obtained by it in connection with the operation of the Facility. Upon receipt of any such Permit, Owner shall promptly provide a copy of such Permit to Contractor. In addition, Owner shall cooperate with Contractor in obtaining any Permit required to be obtained by Contractor in the performance of the Work. Contractor shall provide information reasonably requested by Owner to support Owner’s prosecution of any pending application listed in Exhibit L in respect to the Work and shall perform the Work in compliance with all of the terms and conditions of each of the foregoing Permits. Following Owner’s request, Contractor, on behalf of either Owner or itself, shall timely prepare and file all progress and other reports and any amendments as may be required by or in connection with said Permits and shall otherwise coordinate with any relevant Government Authority as requested by Owner;

3.7.6 obtain, provide and pay for the supply of Feed Gas in accordance with Exhibit A and with the Feed Gas schedule prepared by Contractor in accordance with Section 3.8.11;

 

29


Execution Version

 

3.7.7 supply and, except as otherwise required in Exhibit A, deliver or cause to be delivered to the Job Site or a MOF Facility, as applicable, all of the Owner Furnished Equipment and Materials to be incorporated into the Work, require Owner Contractors to comply with Contractor’s instructions and reasonable requests in support of the Work at the Job Site that do not conflict with an Owner Contract, and perform or cause to be performed the Owner Scope of Work, in each case, in accordance with the requirements set forth in Exhibit A;

3.7.8 during the period commencing on the LPS1 Substantial Completion Date and ending upon the Facility Substantial Completion Date, operate and maintain each LNG Production System Handover Package for which it has assumed care, custody and control hereunder; and

3.7.9 obtain and maintain the insurance set forth in Section 26.3.

 

3.8

RESPONSIBILITIES OF CONTRACTOR.

Without limiting the requirements of any other provision of this Agreement, Contractor shall:

3.8.1 prosecute the Work continuously and diligently in accordance with Owner Standards, all applicable Laws, Permits, Applicable Codes and Standards and in accordance with the Project Schedule, using only qualified and competent personnel, and complete the Work so that the Facility successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the provisions of this Agreement;

3.8.2 ensure that all labor performing at the Job Site will be properly tooled, fully trained and qualified to safely perform the Work in accordance with applicable Law, Permits and Owner Standards;

3.8.3 perform and furnish the Work, including designing, engineering, procuring, manufacturing, packing and transporting, constructing, warranting, Pre-Commissioning, Commissioning, testing, training and directing of operating and maintenance personnel (including the personnel of Owner or its Affiliate) until Facility Substantial Completion, and guaranteeing performance of the Work in accordance with the terms hereof, so that the Facility (a) meets the requirements of all applicable Permits and applicable Laws, (b) meets the requirements of Owner’s property rights with respect to the Job Site identified in Exhibit N, (c) successfully passes the Performance Tests and meets or exceeds the requirements set forth in Exhibit A, Owner Standards and the provisions of this Agreement, (d) meets the requirements of the Applicable Codes and Standards, (e) is safe and adequate for (i) the intended purpose set forth in this Agreement, and (ii) conditions of loading, conveying, storing, metering, liquefying and delivering Feed Gas and LNG, (f) can be operated in a manner consistent with the staffing levels specified in Exhibit Q, (g) is capable of complying with the Laws (including Environmental Laws) issued by any Government Authority or other applicable entities set forth in Exhibit A and Exhibit L, and (h) comprises Materials which are new, are reasonable to maintain, have proven durability to withstand climatic conditions that could reasonably be expected to be experienced at the Job Site, are designed and manufactured in accordance with the requirements set forth in Exhibit A and are assembled and installed in accordance with manufacturer’s specifications and generally accepted standards for the design, manufacture, quality and assembly of such Materials;

 

30


Execution Version

 

3.8.4 obtain and maintain all Permits (including the Permits set forth in Exhibit L that are identified as Contractor Permits, but excluding the Permits set forth in Exhibit L that are identified as Owner Permits) and authorizations from any Government Authority, and administer all such Permits and authorizations required for (a) the design, engineering and construction of the Facility (or any portion thereof), (b) the procurement, handling, supply, shipment, transportation, installation, erection, direction of procurement and testing of the Materials, (c) the installation or integration of the Owner Furnished Equipment and Materials, and (d) the performance of all the Work. Contractor shall provide prompt assistance, information and documentation (including copies of any drawings and design documents) required or requested by Owner for the Work to enable Owner to obtain or modify, or cause to be obtained or modified, the Permits set forth in Exhibit L that are identified as Owner Permits. Contractor shall give Notice to Owner of all conflicts between the requirements set forth herein including Exhibit A and any Laws or Permits that come to the attention of Contractor or with the exercise of reasonable care should have come to the attention of Contractor. Contractor shall assist Owner in obtaining and maintaining all Permits that Owner must obtain pursuant to the terms hereof, including (i) providing information requested by Owner or requested or required by any Government Authority in the possession of, or reasonably obtainable by, Contractor, and (ii) identifying for Owner any Permits that Owner has not obtained, but which Contractor has reason to believe, after due inquiry, must be obtained by Owner for the Contractor’s performance of the Work and/or Owner’s ownership or operation of the Facility. If Contractor performs any of the Work knowing, or when, with the exercise of due care, it should have known, it to be contrary to any such Laws or Permits, such costs shall be Non-Reimbursable Costs. Contractor will provide Owner a copy of its Louisiana Contractor’s License and Louisiana Engineering Firm Registration prior to commencement of the Work;

3.8.5 take full responsibility for the adequacy, stability, cleanliness and safety of Contractor’s (and Subcontractors’) Job Site operations, of Contractor’s (and Subcontractors’) methods of construction and of the Work, irrespective of any approval or consent by Owner, Owner’s Representative or the Independent Engineer;

3.8.6 pay or cause to be paid the Taxes, insurance and bank charges incurred by Contractor or any Subcontractor arising from the performance of its duties under this Agreement;

3.8.7 have joint responsibility with Owner for coordination with Government Authorities, test laboratories and any other Person necessary to demonstrate the Facility’s compliance with all Permits and Laws;

3.8.8 be responsible for claims of Government Authorities, fines and penalties that may arise or be assessed (including those that Owner pays or becomes liable to pay) to the extent caused by Contractor’s or any Subcontractor’s noncompliance with or violation or Laws, Applicable Codes and Standards or Permits;

3.8.9 except as provided in Section 3.7.6 or Exhibit V, obtain all consumables (including construction fuel, construction electricity, water and other utilities and the supply and fill of lubricants, resins, chemicals and the refill and top-off of such lubricants and chemicals following any Performance Tests and other consumables as provided in Exhibit V) necessary for Contractor’s performance of the Work, and Owner’s or its Affiliate’s execution of the Performance Tests,

 

31


Execution Version

 

during the period from commencement of the Work through the Facility Substantial Completion Date;

3.8.10 obtain all internet access, telephone and radio usage necessary for Contractor’s performance of the Work and for each Owner Contractor’s performance of its respective services and work during the period from commencement of the Work through the Facility Substantial Completion Date;

3.8.11 determine sufficiently in advance the quantities of Feed Gas, in MMBtu, that will be required for each Day on which Commissioning activities and the Performance Tests in respect of each LNG Production System will be conducted as provided in Exhibit A and Exhibit R;

3.8.12 perform all Work necessary for the Feed Gas Interconnections specified in Exhibit A at the Facility and Pipeline Tie Point(s);

3.8.13 without limiting Owner’s obligations under Section 3.7.1, (a) until the earlier of the Facility Substantial Completion Date or termination of this Agreement, be responsible for the management of the Job Site (including (i) any construction routes between the road used to access the Job Site and the Job Site and within the Job Site boundaries, (ii) coordination of Subcontractors’ activities and the management of all common areas within the Job Site so as to optimize Contractor’s and Subcontractors’ performance, (iii) provide any signs or directions which they may consider necessary for the guidance of its staff, labor and others, and (iv) maintain the Job Site at all times free of waste material and rubbish), (b) upon the earlier of Final Completion or termination of this Agreement, clear the Job Site of temporary structures, surplus items (unless Owner requests such surplus items be left at the Job Site), construction equipment and tools, (c) until the earlier of the Facility Substantial Completion Date or termination of this Agreement, provide all reasonable and necessary safeguards, including fencing, signs, security services, fire protection and the like, for the health, safety, security and protection of the Job Site, the Work and the Facility and of all Persons and property related thereto, and (d) until the earlier of the Facility Substantial Completion Date or termination of this Agreement, keep unauthorized Persons off of the Job Site and reconstruct, repair or replace Materials or property of Contractor which may be stolen or damaged by vandalism;

3.8.14 take all reasonable steps to protect the environment and to limit damage and nuisance to people and property resulting from pollution, construction noise and other results of the performance of the Work, and ensure that the Work and any Releases, including construction air emissions, surface discharges and effluent, from its performance of the Work shall be in compliance with all applicable Permits, Applicable Codes and Standards and Laws;

3.8.15 within ninety (90) days following the earlier of (a) Facility Substantial Completion Date or (b) earlier termination of this Agreement as provided herein, (i) assist Owner in preparing an inventory of all Materials (wherever located), special tools, construction aids and all other Contractor or Subcontractor materials, equipment, supplies purchased and used in connection with the Work (the “Surplus Construction Materials”), and (ii) transfer, or cause the transfer, of possession and title to Owner of all Surplus Construction Materials that Owner elects to take possession of by Notice to Contractor;

 

32


Execution Version

 

3.8.16 provide reports, information and data as will be necessary for Owner to maintain segregated accounts of the Work for Owner’s records where required by Law or generally accepted accounting principles in the United States of America. Such segregation will include separate accounting for expenditures with respect to buildings, land improvements, engineering and project management, Materials, Feed Gas Interconnections, Permit costs and Taxes paid by Contractor;

3.8.17 if (a) a Dispute under this Agreement arises in connection with a default or termination of this Agreement, or Owner’s obligation to pay certain Taxes hereunder, (b) a Change Order payment is to be determined on a cost-plus basis (at the then applicable labor rates then set forth in Exhibit C) or (c) the Work is accelerated pursuant to Section 16.3.2, then, in each case, grant to Owner sufficient audit rights with respect to all documentation pertaining thereto (excluding, in all cases, the build-up of any fixed price, any multiplier or other lump-sum amounts). Owner shall have the right to choose an independent certified public accounting firm to act as auditor for such an audit and the reasonable cost of any audit will be borne by the Party whose position is not substantially supported by the results of such audit. Audit data shall not be released by such auditor to Persons other than Contractor, Owner, the Independent Engineer, the Lenders or their respective employees and agents in connection with any such audit and Owner and Contractor shall treat such audit data as confidential, but shall not be precluded from using such audit data in any legal or arbitration proceedings arising under this Agreement in relation with the Dispute or Change Order;

3.8.18 make available to Owner and Owner Contractors at all times during the term hereof sufficient storage areas and personnel at each MOF Facility for the unloading, handling, preservation, storage, loading and transportation of all Owner Furnished Equipment and Materials delivered to such MOF Facility by an Owner Contractor, and not take or omit to take, and cause its Affiliates not to take or omit to take, any action with respect to such MOF Facility that would prevent, impede, delay or otherwise hinder Contractor’s performance of the Work in accordance with this Agreement;

3.8.19 arrange and/or ensure the complete handling of all equipment, machinery, Materials and spare parts required for the Work, including the inspection, expediting, shipping and transport, unloading, receiving, storage and payment of all Taxes imposed on Contractor or its Subcontractors and incurred in connection therewith, and arrange for proper safe keeping, handling, preservation, storage, maintenance and transportation at, to or from a MOF Facility or the Job Site, as applicable, for such equipment, machinery, Materials and spare parts;

3.8.20 coordinate customs expediting and clearance services and logistics at the Job Site with a qualified company selected by Owner and perform all administrative formalities in connection therewith, including obtaining all approvals, certificates, documents and licenses which may be pertinent and/or necessary for Contractor’s equipment, machinery, Materials and spare parts required for the Work, all in a timely manner;

3.8.21 transport from each MOF Facility to the Job Site all Owner Furnished Equipment and Materials delivered to such MOF Facility in accordance with the Project Schedule;

3.8.22 provide for all temporary construction materials, equipment, supplies and facilities necessary for the performance of the Work;

 

33


Execution Version

 

3.8.23 upon Notice from Owner, replace (a) any Subcontractor who fails to perform its Subcontract obligations, and (b) replace any of Contractor’s personnel, and cause any Subcontractor to replace its personnel, performing the Work if (i) Owner believes that such personnel are negligently performing the Work or that such personnel are creating a risk to the health and/or safety of Persons or property or (ii) Owner believes that such personnel are otherwise not performing the Work in accordance with Owner Standards or are creating a risk to the timely completion of the Work in accordance with this Agreement;

3.8.24 provide all special tools, construction/Commissioning spare parts and supplies required for operation of the Facility (excluding all special tools, construction/Commissioning spare parts and supplies provided as part of the Owner Furnished Equipment and Materials) until the Facility Substantial Completion Date, at which time all special tools and other supplies required for the operation of the Facility that are supplied by Contractor shall be transferred to Owner in accordance with Section 3.8.15;

3.8.25 use only the entrance(s) to the Job Site designated by Owner and applicable Permits for ingress and egress of all personnel and vehicles and for the delivery of all Materials;

3.8.26 provide such assistance as is requested by Owner in dealing with the Lenders, the Independent Engineer or any Government Authority in any and all matters relating to the Work and the Facility; provided that no review, approval or disapproval by the Independent Engineer shall serve to reduce or limit the liability of Contractor hereunder;

3.8.27 cooperate with Owner’s Representative and designee and the Independent Engineer in the review of design materials, the conduct of inspections and Commissioning, and in any other matters hereunder relating to the Work and respond promptly to inquiries from Owner;

3.8.28 provide all operating instructions, procedures, data and manuals, spare parts manuals, integrated and coordinated operation and maintenance manuals and training aids in accordance with the Drawings and Specifications;

3.8.29 train and certify the operating and maintenance personnel in accordance with Exhibit G;

3.8.30 perform the Pre-Commissioning and Commissioning and direct the operation and maintenance personnel (including the personnel of Owner or its Affiliate) during Pre-Commissioning, Commissioning and execution of the Performance Tests in full accordance with the written operating instructions, the operations and maintenance manuals and the safety procedures;

3.8.31 obtain Owner’s prior written approval (which approval may be withheld in Owner’s sole discretion and for any reason) of the text of any announcement, publication, photograph or other type of communication concerning the Work prior to the dissemination or release of same by Contractor or its Subcontractors;

3.8.32 subject to Owner’s prior approval, designate the Contractor’s Representative who will have full responsibility for the prosecution of the Work in respect of this Agreement and act as a single point of contact with Owner, Owner Contractors and Pipeline Contractor in all matters

 

34


Execution Version

 

on behalf of Contractor. Upon the reasonable written request of Owner, Contractor shall promptly replace the Contractor’s Representative. Subject to Section 5.2, Contractor shall not replace the Contractor’s Representative without the prior written consent of Owner, which consent shall not be unreasonably withheld. The Contractor’s Representative shall be available at the Job Site and elsewhere, when reasonably required, at all reasonable times for consultation and, if absent, shall designate a suitable alternate to act as the Contractor’s Representative during such absence;

3.8.33 during the performance of the Work, maintain continuously at the Job Site adequate management, supervisory, administrative, security, safety, quality and technical personnel, to ensure expeditious and competent handling of all matters related to the Work, according to its determination of the staffing required for this purpose and Exhibit Y. Contractor shall designate the Key Personnel as set forth in Exhibit K;

3.8.34 provide such data, reports, certifications, certified copies of organizational documents, resolutions, incumbency certificates, audited financial statements, opinions of counsel and other documents or assistance as may be (a) requested by Owner, the Lenders or Owner’s title insurance providers with respect to the Financing or otherwise requested by Owner in connection with the performance of this Agreement or (b) requested or required by any Government Authority with respect to any Permits or regulatory filings;

3.8.35 advise Owner of negotiations with Major Subcontractors concerning the availability of improved warranties or guarantees related to major items of Materials to be incorporated into the Facility;

3.8.36 (a) cooperate with and provide information reasonably requested by Owner to support Owner in performing, or causing the performance of, the Owner Scope of Work and the delivery of the Owner Furnished Equipment and Materials to the Job Site or a MOF Facility, as applicable; (b) receive, transport and unload at the Job Site, or a MOF Facility or a storage yard designated by Owner for transshipment to the Job Site, all Owner Furnished Equipment and Materials; (c) perform the construction management services relating to the scheduling and coordination of the work and services performed by the Owner Contractors under the Owner Contracts and the administration and reporting to Owner of the performance by each Owner Contractor of its obligations of the relevant Owner Contract(s); and (d) install and integrate the Owner Furnished Equipment and Materials into the Facility;

3.8.37 coordinate and perform the applicable portion of the Work under the oversight and direction of BH personnel that are present at the Job Site or a MOF Facility pursuant to the Field Services Agreement;

3.8.38 maintain qualified personnel on the Job Site to consult with Owner regarding the operation and maintenance of the Facility (a) during Pre-Commissioning, Commissioning, startup and testing of each LNG Production System and the Facility, (b) until successful completion of the training program required by Article 14, and (c) in accordance with the Warranty procedures set forth in Article 20 during the Warranty Period (which does not require Contractor to maintain personnel on the Job Site);

3.8.39 comply with the Warranty procedures set forth in Article 20;

 

35


Execution Version

 

3.8.40 in accordance with Article 39, cooperate with Owner in obtaining suitable Financing in accordance with the Lenders’ requirements;

3.8.41 provide complete Deliverables and follow them during the performance of the Work;

3.8.42 prepare and keep up-to-date on a daily basis a complete set of red-lined “as-built” records of the execution of the Work, showing the “as-built” locations, sizes and details of the Work as executed, with cross references to relevant specifications and data sheets, which records shall be kept on the Job Site and shall be made available to Owner upon request;

3.8.43 prepare and submit to Owner “as-built” drawings (in accordance with Exhibit J) of the Work showing the process-related portions of the Work as executed. The “as-built” drawings shall be provided in their native file format, red-lined as the Work proceeds, and shall be submitted at least monthly (and more frequently as requested by Owner) to Owner for its inspection;

3.8.44 submit to Owner, within sixty (60) Days following the Facility Substantial Completion Date or upon termination of this Agreement, five (5) electronic files in a format designated by Owner, one (1) full-size original copy and six (6) printed copies of the relevant final “as-built drawings” (in accordance with Exhibit J) and any further construction documents relating to the Work reasonably requested by Owner, all prepared in accordance with this Agreement;

3.8.45 in accordance with Article 9, submit to Owner the applicable Performance Security;

3.8.46 refrain from bringing, and not permit or allow any Subcontractor or other Person (other than an Owner Contractor acting in accordance with the relevant Owner Contract or the Pipeline Contractor) to bring, any Hazardous Substances on the Job Site and bear all responsibility and liability for such materials brought to the Job Site by Contractor or its Subcontractors; provided, however, that Contractor and Subcontractors may bring onto the Job Site such Hazardous Substances as are necessary to perform the Work so long as the same is done in compliance with applicable Laws, Permits, and Applicable Codes and Standards, and Contractor shall remain responsible and liable for all such Hazardous Substances. Contractor shall maintain an updated record and current inventory of all Hazardous Substances brought onto the Job Site or used by Contractor or any Subcontractors in connection with the performance of the Work, which records shall identify types, quantities, location of storage, use and final disposition of such Hazardous Substances, and shall promptly make such file available to Owner at the Job Site upon preparation and any updates. If Contractor or any of its Subcontractors cause, exacerbate or permit a Release of any Hazardous Substances on, at, under or from the Job Site, Contractor shall, at its sole cost and expense: (a) immediately notify Owner in writing; (b) comply with all applicable Laws, Permits and Applicable Codes and Standards and take all necessary steps to protect human health and the environment, and shall not exacerbate such condition; and (c) diligently proceed to take all necessary actions to clean up fully any contamination or impacts resulting therefrom. If Contractor or any of its Subcontractors encounter a Release of any Hazardous Substances on, at, under or from the Job Site that is not caused, exacerbated or permitted by any of them or any Pre-Existing Hazardous Substances, Contractor shall: (a) immediately notify Owner in writing; (b) comply with all applicable Laws, Permits and Applicable Codes and Standards and take all necessary steps to protect human health and the environment, and shall not exacerbate such

 

36


Execution Version

 

condition; and (c) diligently proceed to take all necessary actions to assist Owner’s efforts to clean up fully any contamination or impacts resulting therefrom;

3.8.47 during the performance of the Work, maintain an office at the Job Site, in a temporary or permanent structure that shall be subject to the approval of Owner, which shall serve as the offices for Contractor, Owner and Owner Contractors, and upon completion of the Work, leave such offices, which shall remain the property of Owner, in a clean condition satisfactory to Owner;

3.8.48 cooperate and cause the Subcontractors to cooperate with Owner, Owner Contractors, the Pipeline Contractor and other unrelated contractors who may be working at or near the Job Site in accordance with the Project Schedule in order to assure that neither Contractor nor any of the Subcontractors unreasonably hinders or increases or makes more difficult the work being done by or on behalf of Owner, the operation of the Facility and other unrelated contractors at or near the Job Site;

3.8.49 use reasonable efforts, and cause the Subcontractors to use their reasonable efforts, to assist Owner in creating, assessing and carrying out programs which shall, during all phases of the Work, minimize the impacts on the host community caused by completion of the Work;

3.8.50 pay all Subcontractors in a timely fashion in accordance with the respective Subcontracts and provide Owner with Notice of any material dispute regarding the Work that is pending or threatened, which Notice shall detail the dispute, the parties involved and identify any Subcontractors that Contractor intends to withhold payment from and the amount to be withheld;

3.8.51 obtain and maintain the insurance set forth in Section 26.2. Contractor shall (a) cooperate with Owner so that Owner may obtain and maintain the insurance set forth in Section 26.3, including providing any information reasonably required by insurance carriers providing such insurance, and (b) comply with the requirements of the insurance policies provided by Owner pursuant to Section 26.3, including providing information necessary to substantiate any claims filed under such policies;

3.8.52 in accordance with Article 23, ensure that all agreements, guarantees, warranties, delivery schedules and performance requirements with Subcontractors comply with the requirements of this Agreement;

3.8.53 in accordance with Article 40, comply with the requirements of the Anti-Corruption Laws and Export Controls;

3.8.54 in accordance with Section 3.9, obtain recommendations for spare parts for the operation and maintenance of the Facility and, if requested by Owner, procure and deliver the Spare Parts to the Job Site;

3.8.55 as applicable comply in all respects with the requirements, prohibitions, and other obligations applicable to a general contractor under Louisiana’s Private Works Act, Louisiana Revised Statute 9:4801, et seq.;

 

37


Execution Version

 

3.8.56 as applicable after the issuance of the Notice to Proceed (or, if required by Law in connection with the performance of the scope under any Limited Notice to Proceed, the Limited Notice to Proceed) properly and timely file written notice of contract (the “Notice of Contract”), together with performance and payment bonds attached, if required, and a “no work” affidavit satisfying the requirements of Louisiana Revised Statute 9:4820.C. for registry with the recorder of mortgages of the parish in which the Work is to be performed. Preparation and filing of the notice of contract and bonds shall comply with Louisiana’s Private Works Act, La. R.S. 9:4801, et seq.;

3.8.57 as applicable upon Final Completion, file a notice of termination for registry with the recorder of mortgages for Plaquemines Parish, referencing the Notice of Contract, and satisfying the requirements of Louisiana Revised Statute 9:4822.E.;

3.8.58 as applicable as a condition precedent to final payment by Owner hereunder, supply to Company a Clear Lien and Privilege Certificate for the Facility from the recorder of mortgages for Plaquemines Parish, which certificate is dated after the expiration of the period during which Subcontractors and suppliers may file valid claims or liens pursuant to Louisiana’s Private Works Act, LA. R.S. 9:4801, et seq.; and

3.8.59 as applicable as a condition precedent to final payment by Owner hereunder, at Owner’s request, Contractor shall file, or concur with the filing of, a request for cancellation of the Notice of Contract pursuant to Louisiana Revised Statute 9:4832.A.

 

3.9

SPARE PARTS.

3.9.1 Promptly following Contractor’s issuance of a Subcontract, Contractor shall deliver to Owner a detailed list (that shall include pricing information) of all Subcontractor and Contractor-recommended capital spare parts, other spare parts and special tools necessary for operating and maintaining the Facility (excluding all spare parts and special tools supplied as part of the Owner Furnished Equipment and Materials), including components and systems of the Facility (collectively, “Spare Parts”), following each LNG Production System Substantial Completion Date and the Facility Substantial Completion Date. At any time prior to the Final Completion Date, Owner shall specify in writing which items on the list it wishes Contractor to purchase and whether such items are requested to be delivered to the Job Site prior to LNG Production System Substantial Completion for an LNG Production System, Facility Substantial Completion or Final Completion, as applicable. For those Spare Parts Owner directs Contractor to purchase, Contractor shall purchase such Spare Parts on the best available commercially reasonable terms (including all rebates and discounts). In addition to ordering and purchasing the Spare Parts as provided above, Contractor shall receive, inspect, deliver to storage and take all other reasonable actions for the storage and maintenance of the Spare Parts until the Final Completion Date.

3.9.2 Contractor shall properly store and categorize all spare parts provided pursuant to Section 3.9.1 in order to preserve such spare parts and prevent corrosion, and shall create and maintain a computerized inventory of all such spare parts. Contractor shall submit the inventory control system to Owner for review and such inventory control system shall be approved by Owner prior to its implementation. Contractor shall cause the inventory control system to be transferred

 

38


Execution Version

 

to Owner’s computer system at the Facility prior to the LPS1 LNG Production System Substantial Completion Date. Any spare parts purchased by Owner that are present at the Job Site prior to Owner’s assumption of the care, custody and control of the Facility pursuant to Section 18.1.3 and during the Warranty Period may be reasonably used by Contractor following written permission by Owner; provided, however, that Contractor shall be required to replace such spare part with an identical new replacement on an expedited basis.

 

3.10

PROCUREMENT.

3.10.1 Within [***] Days after the date of issuance of the Notice to Proceed, Contractor shall provide Owner with an estimated schedule of the planned air, marine and land shipments for which Contractor is responsible, identifying (a) equipment estimated to be essential to the Critical Path, (b) the equipment and values to be contained in each shipment, and (c) other specific information reasonably required by insurance underwriters (including the vessel and/or vehicle identification, the itinerary and schedule along with scheduled shipping dates from each MOF Facility or Contractor’s, a Subcontractor’s or their supplier’s warehouse) (collectively, the “Shipping Information”). Thereafter, in order for Owner to secure insurance for each marine, air and land shipment made by Contractor, Contractor shall provide monthly updates to Owner and Owner’s designated cargo insurer of any changes to the Shipping Information. Contractor shall not permit any shipment to be made until such Notice is timely given to Owner. Shipping delays incurred by Contractor or any Subcontractor as the result of delays in securing cargo insurance to the extent due to Contractor’s failure to supply such Notice on a timely basis shall not be the basis for an Owner Caused Delay. Contractor shall ensure that all shipments of cargo by Contractor or any Subcontractors comply with requirements related thereto of such insurance providers.

3.10.2 Each shipment manifest of Contractor and any Subcontractor will be prepared in a format consistent with the requirements of Owner.

 

4.

COMMENCEMENT OF THE WORK.

 

4.1

NOTICE TO PROCEED.

4.1.1 Owner may issue to Contractor a Notice in the form attached hereto as Exhibit F-13 (the “Notice to Proceed”) specifying the date for full commencement of the Work (the “Notice to Proceed Date”), which date shall not be prior to the date that Contractor receives the Notice to Proceed. Subject to any Limited Notice to Proceed, Contractor shall commence the Work only after the Notice to Proceed Date specified in the Notice to Proceed and thereafter diligently pursue the Work, assigning to it a priority that will ensure LNG Production System Substantial Completion of each LNG Production System on or before the applicable LNG Production System Substantial Completion Deadline, Facility Substantial Completion on or before the Facility Substantial Completion Deadline and Final Completion on or before the Final Completion Deadline. Contractor shall proceed with the performance of the Work in accordance with the Project Schedule; provided, however, that any failure of Contractor to pursue the Work in accordance with the Project Schedule shall not relieve Contractor of any liability hereunder.

4.1.2 Prior to the issuance of the Notice to Proceed, Owner intends to obtain sufficient funds from one or more Lenders to fulfill its payment obligations under this Agreement. Owner

 

39


Execution Version

 

shall not issue the Notice to Proceed until the date on which it has obtained written and binding commitments in respect of such funds.

4.1.3 On or prior to Owner’s issuance of the Notice to Proceed pursuant to this Section 4.1, Contractor shall provide the Performance and Payment Bonds to Owner as required pursuant to Article 9.

4.1.4 Issuance of the Notice to Proceed is contingent upon FERC issuing the FERC Authorization. In the event FERC denies Owner’s application for the FERC Authorization or the content of such FERC Authorization is not acceptable to Owner, then Owner shall not be obligated to appeal therefrom. In the event FERC denies Owner’s application, then Owner may terminate this Agreement for convenience in accordance with Article 32.

 

4.2

LIMITED NOTICES TO PROCEED.

4.2.1 Prior to the issuance of the Notice to Proceed, Owner shall have the right to issue one or more limited notices to proceed directing Contractor to commence and complete any portion of the Work specified in any such limited notice to proceed and subject to the terms of this Agreement substantially in the form attached hereto as Exhibit F-8 (each, a “Limited Notice to Proceed”), except as otherwise agreed by Owner and Contractor. All activities required to be performed thereunder shall be done in accordance with the requirements for the Work hereunder. Contractor shall not be required to commence performance of the Work described in a Limited Notice to Proceed until it has counter-signed the Limited Notice to Proceed. All Work performed by Contractor under a Limited Notice to Proceed shall be compensated by Owner on the same basis as provided in Exhibit B, and one hundred percent (100%) of such payment shall be credited as an offset against subsequent Reimbursable Costs, Contractor’s G&A and Contractor’s Margin owed by Owner to Contractor, as applicable; provided that Contractor’s Margin earned prior to issuance of the Notice to Proceed shall not be payable to Contractor until the earlier to occur of (i) the issuance of the Notice to Proceed, and (ii) the termination of this Agreement. Upon issuance of the Notice to Proceed, all such performance of the Work under a Limited Notice to Proceed shall constitute Work done pursuant to this Agreement.

 

5.

PERSONNEL AND QUALIFICATIONS.

 

5.1

GENERAL.

5.1.1 Contractor represents to Owner that it, its designers and its design Subcontractors have the experience and capability necessary for the design and performance of the Work. Contractor undertakes that its personnel and design Subcontractors shall be available to attend discussions with Owner and the Independent Engineer at all times at the Job Site or other mutually agreed locations during the performance of the Contractor’s obligations hereunder.

5.1.2 Contractor, all Subcontractors and all personnel used by Contractor and Subcontractors in the performance of the Work shall be qualified by training, licenses or certifications, as required, and experienced to perform their assigned tasks. Contractor shall not use in the performance of the Work any personnel reasonably deemed by Owner to be incompetent, careless, unqualified to perform the work assigned to them, unsafe, creating an unsafe work environment or interfering with the completion of the Work. Notwithstanding the foregoing,

 

40


Execution Version

 

Owner shall have no liability and Contractor agrees to release indemnify, defend and hold harmless each Owner Indemnitee from and against any and all Losses, of whatsoever kind or nature, which may directly or indirectly arise or result from Contractor or any Subcontractor terminating the employment of or removing from the Work any such employee who fails to meet the foregoing requirements following a request by Owner to have such employee removed from the Work.

5.1.3 Contractor shall maintain labor relations in such a manner that, so far as reasonably practicable, there is harmony among workers. Contractor and the Subcontractors shall conduct their labor relations in accordance with the recognized prevailing local area practices, applicable Law, Permits, Applicable Codes and Standards and Owner Standards.

 

5.2

KEY PERSONNEL.

The Contractor’s organizational structure for the performance of the Work is provided in Exhibit K. Prior to the commencement of the Work, the Key Personnel shall hold the positions indicated in Exhibit K. Contractor acknowledges and agrees that the continuity of Key Personnel in connection with the Work is a material requirement of this Agreement and that the replacement of any Key Personnel will be detrimental to Owner and the overall quality of the Work. The Key Personnel will be engaged full-time and exclusively in the prosecution of the Work continuously until their role is completed, unless prior release is approved or directed by Owner; provided however, Key Personnel may be removed by Contractor without Owner’s consent for (a) termination of a Key Personnel’s employment with the Contractor or its Affiliates, or (b) a Key Personnel dying, retiring, resigning, or becoming seriously ill, or a serious illness or death in the family of a Key Personnel. Revisions to the organizational structure of Key Personnel shall be subject to Owner’s prior approval, and replacement of, or additions to, such Key Personnel shall only be made with persons having qualifications equal to or better than those replaced or added to, and shall be similarly subject to Owner’s prior approval. All requests for the substitution of Key Personnel shall include a detailed explanation and reason for the request and the resumes of professional education and experience for a minimum of two (2) candidates of suitable qualifications and experience. Should Owner approve of the replacement of a Key Personnel, Contractor shall allow for an overlap of a minimum of two (2) weeks during which both the Key Personnel to be replaced and the Owner-approved new Key Personnel shall work together full time. Owner may if it is concerned with the performance thereof request in writing the removal of, and Contractor shall promptly remove and replace, any Key Personnel. Contractor agrees that, notwithstanding its other business commitments, it will give the Work a priority and commit sufficient resources to the Work that will enable Contractor to perform its obligations under this Agreement.

 

6.

PRICE AND PAYMENT.

 

6.1

TARGET PRICE.

6.1.1 The “Target Price” is equal to [***], the principal components of which are more fully described in Exhibit B-3, as the foregoing may be adjusted from time to time pursuant to a Change Order, to be paid pursuant to Section 6.3.

 

41


Execution Version

 

6.1.2 Contractor has satisfied itself as to the correctness and sufficiency of the Target Price and represents to Owner that the Target Price is a valid estimate of the Direct Costs and the Contractor’s G&A and Contractor’s Margin applicable thereto that will be paid to Contractor for the performance of the Reimbursable Work. The Target Price includes the estimated costs for the Materials, labor, transportation, services and Intellectual Property rights forming part of the Reimbursable Work and, including the costs of Materials, transportation and storage of Materials and all Taxes other than sales and use taxes, duties and tariffs for which Contractor is responsible hereunder, the cost to Contractor to provide the Performance Security, and Contractor’s estimated cost for repair or replacement of all Defects and Deficiencies and other corrective Work prior to the commencement of the Warranty Period, including as described in Exhibit B-1.

6.1.3 The Parties acknowledge that prior to the Notice to Proceed Date, Owner and Contractor have met and will continue to meet and discuss adjustments to the components of the Work identified in Exhibit W (the “Open Cost Items”), and their associated values and schedule impacts (if any), on an open book basis, with a view to incorporating the Open Cost Items (if necessary) into the Work. The Parties will use good faith efforts to reach agreement on the final value and scope of Open Cost Items on or before September 30, 2023 and acknowledge that such agreement shall be a condition to Owner’s Financing. Following the Parties’ agreement on the Open Cost Items, Owner shall issue a Change Order to reflect the adjustments for the Open Cost Items.

 

6.2

[RESERVED].

 

6.3

PAYMENT.

6.3.1 Not later than the 15th day of each Month N, Contractor shall submit to Owner for its approval a Request for Payment (simultaneously sending copies to the Independent Engineer, as Owner may direct), which shall set forth: (a) a reasonable good faith estimate of (i) the Reimbursable Work activities that will be performed during the second month (“Month N+2”) immediately following such Month N, and (ii) the Direct Costs, Contractor’s G&A and Contractor’s Margin (including details of Margin Milestones anticipated to be achieved) associated with such Reimbursable Work activities (the sum of clauses (i) and (ii) being referred to herein as an “Estimated Monthly Amount”); (b) except for the Initial Request for Payment, the amount owed to Contractor in respect of the Reimbursable Work performed during the preceding month(s), together with Contractor’s G&A and Contractor’s Margin associated with such Reimbursable Work, that has not been paid to Contractor during such preceding month(s), as applicable; (c) except for the Initial Request for Payment, the amount by which the aggregate amount of Estimated Monthly Amounts paid to Contractor during the preceding month(s) exceeds the actual Direct Costs incurred by Contractor in the performance of the Reimbursable Work during the preceding month(s), calculated as of the last day of the month immediately preceding such month, and the Contractor’s G&A and Contractor’s Margin associated with such Direct Costs payable by Owner in respect of such Reimbursable Work; (d) any other amounts that may be due and owing from Owner to Contractor or from Contractor to Owner pursuant to any other provision of this Agreement; and (e) all information and documentation required by Section 6.3.3.

6.3.2 Owner shall, with respect to the Initial Request for Payment, make payment of the net amount specified in such Request for Payment within fifteen (15) Business Days of its receipt

 

42


Execution Version

 

of such Request for Payment and with respect to each subsequent Request for Payment in accordance with Section 6.6.

6.3.3 Each Request for Payment submitted by Contractor pursuant to Section 6.3.1 will be accompanied by: (a) a certificate of release and waiver of liens (other than Permitted Liens) from Contractor in the form attached hereto as Exhibit F-1; (b) a Payment Status Affidavit from Contractor in the form attached hereto as Exhibit F-15; (c) certificates of release and waiver of liens (other than Permitted Liens) from each Major Subcontractor providing Materials or services described in the Request for Payment in the form attached hereto as Exhibit F-2; (d) a Payment Status Affidavit from each Major Subcontractor in the form attached hereto as Exhibit F-16; (e) a Monthly Progress Report pursuant to Section 13.3; (f) a report of Defects and Deficiencies pursuant to Section 10.2.1; (g) supporting documentation evidencing the Reimbursable Costs and Contractor’s G&A that are defined in Exhibit B-1; (h) the aggregate accrued amount of the Contractor’s Margin (with supporting calculations) of which payment is requested in respect of the Margin Milestone(s) that have occurred in the previous month; and (i) any other information that Owner, the Lenders or the Independent Engineer may reasonably request (provided Contractor is given a reasonable period of time to satisfy such request prior to Contractor’s submission of a Request for Payment). Contractor shall itemize Taxes (which are Reimbursable Costs) by category and cost component, including Louisiana state and local sales/use tax and any other sales/use tax that Contractor may be responsible for collecting from Owner (by state and taxing jurisdictions), import duties, and sales tax of other states (by other state). Contractor shall only include Direct Costs in a Request for Payment in accordance with the rates and other provisions set forth in Exhibit B-1 and Exhibit C.

6.3.4 Amounts (a) owed by Owner to Contractor, and (b) owed by Contractor to Owner shall, to the extent not paid when due pursuant to the terms hereof, accrue interest at the Late Payment Rate from the date payment thereof was due until the date of payment thereof in full (together with all accrued interest).

6.3.5 In no event shall the payment of any amount by Owner to Contractor constitute an acceptance of any Work, and Owner’s acceptance of the Work shall not relieve Contractor of any of its obligations hereunder.

6.3.6 Notwithstanding anything to the contrary contained herein, failure by Owner to pay any amount in dispute until resolution of such dispute in accordance with this Agreement shall not alleviate, diminish, or modify in any respect Contractor’s obligations to perform hereunder.

6.3.7 Notwithstanding anything to the contrary contained herein, except as expressly set forth in a Limited Notice to Proceed, Contractor shall not be obligated to perform any further Work and Owner shall not be obligated to make any further payment hereunder until after the Financial Closing Date has occurred.

6.3.8 Contractor’s Margin shall only be payable as and when required pursuant to, and in the amounts specified in, the Margin Milestones. For the avoidance of doubt, no Contractor’s Margin in respect of any Margin Milestone shall be due and payable by Owner until such Margin Milestone has been achieved by Contractor, such achievement being confirmed by a Certificate of Achievement to be provided by Contractor together with the relevant Request for Payment. For

 

43


Execution Version

 

the avoidance of doubt, no Margin Milestone shall be due and payable by Owner until such Margin Milestone has been achieved by Contractor.

6.3.9 All Non-Reimbursable Costs shall be borne exclusively by Contractor. Contractor shall not include any Non-Reimbursable Costs in a Request for Payment or otherwise seek reimbursement from Owner of any Non-Reimbursable Costs.

6.3.10 Owner shall have the right to audit all documentation pertaining to each Request for Payment on reasonable prior notice to Contractor and during normal business hours in order to confirm the accuracy and completeness of such Request for Payment. Notwithstanding the foregoing, and without prejudice to Owner’s rights under Sections 3.8.17 and 40.2, Owner shall have no right to audit or inspect the internal composition of any Contractor’s rates, the make-up or composition of Contractor’s lump sum pricing, unit prices, unit rates, fixed rates, fixed percentages, multipliers or any other form of fixed pricing, or of costs which are expressed in terms of percentages of other costs.

6.3.11 The Parties acknowledge that the amount of Contractor’s Margin payable by Owner in respect of each Margin Milestone is calculated based on a percentage of the then applicable Base Target Price. The following methodology will be applied with respect to any (i) adjustment to the Base Target Price after the Effective Date, (ii) instance where the aggregate amount of Direct Costs (other than Tax Costs) incurred in the performance of the Reimbursable Work exceeds the then applicable Base Target Price or (iii) early termination of this Agreement:

(a) Upon an increase to the Base Target Price, the amount payable for each Margin Milestone in respect of which Contractor’s Margin has previously been paid shall be automatically increased to reflect the applicable milestone percentage of the amount of the increase to the Base Target Price, and the positive difference between such increased amount payable and the amount previously paid shall be invoiced by Contractor to Owner in the next following Request for Payment; provided, however, that any portion of the increase to the Base Target Price that has previously been invoiced to Owner and paid in accordance with clause (c) of this Section 6.3.11 shall be excluded from the application of this clause (a).

(b) Upon a decrease to the Base Target Price, the amount payable for each Margin Milestone in respect of which Contractor’s Margin has previously been paid shall be automatically decreased to reflect the applicable milestone percentage of the amount of the decrease to the Base Target Price, and the positive difference between the amount previously paid and such decreased amount payable shall be applied as a credit to Owner in the next following Request for Payment.

(c) If at any time the aggregate amount of Direct Costs incurred in the performance of Reimbursable Work exceeds the then applicable Base Target Price, payments of Contractor’s Margin for all Margin Milestones shall be recalculated by applying such aggregate amount in place of the Base Target Price in the definition of “Contractor’s Margin”, and the positive difference resulting from such recalculation shall, with respect to each Margin Milestone in respect of which Contractor’s Margin has previously been paid, be invoiced by Contractor to Owner in the next following Request

 

44


Execution Version

 

for Payment; provided, however, that the Contractor’s Margin shall not be adjusted pursuant to this clause (c) more than once every ninety (90) days.

(d) If this Agreement is terminated pursuant to and in accordance with Articles 31 or 32, the amount of Contractor’s Margin owed to Contractor upon such termination shall be calculated on the basis of all Direct Costs (other than Tax Costs) incurred in the performance of Reimbursable Work prior to the date of such termination rather than the Appendix 1 of Exhibit D Margin Milestone payment schedule. If the amount of Contractor’s Margin calculated pursuant to the preceding sentence is greater or less than the aggregate amount of Contractor’s Margin paid to Contractor prior to the date of such termination, the difference shall be paid to Contractor or Owner, respectively.

 

6.4

ENCUMBRANCES.

6.4.1 Contractor covenants and agrees that, with the sole exceptions of (a) an arbitral or Government Authority’s decision in Contractor’s favor, and (b) Permitted Liens, no mechanics’ liens, similar liens or any encumbrances whatsoever shall be filed or maintained by Contractor, any Subcontractor or worker or other Person acting, directly or indirectly, through or under Contractor or any Subcontractor, against the Job Site, the Facility (or any portion thereof), any Materials or Owner Furnished Equipment and Materials, any land or improvements pertinent thereto, for or on account of any Work done or to be done or Materials furnished or to be furnished hereunder (the foregoing types of liens, regardless of who files them, collectively, the “Indemnified Liens”). Any lien or encumbrance filed by Contractor shall be limited in scope to secure payment by Owner of the amount at issue in any applicable dispute resolution proceeding. Upon Owner’s payment of such amount, Contractor shall immediately, and in any event within seven (7) Days of such payment, effect release (and certify thereto) of any such lien or encumbrance. For the avoidance of doubt, if a dispute resolution proceeding is brought within the applicable statute of limitations, but the outcome of such proceeding is not determined until after the statute of limitations has expired, the Parties agree to waive the statute of limitations in order to effect the outcome of such dispute resolution proceeding.

6.4.2 If Contractor fails to satisfy the obligation set forth in Section 6.4.1 within thirty (30) days, Contractor agrees, to the fullest extent permitted by Law, to indemnify and hold harmless each of the Owner Indemnitees and the Owner’s title insurers against any and all Losses associated with any Indemnified Lien and Owner shall have the right to (a) consider the amount of the lien or encumbrance as presumptively correct, (b) withhold from any payment to Contractor then due, or thereafter to become due (including the Final Request For Payment), an amount sufficient to completely indemnify Owner Indemnitees against such lien or encumbrance, (c) pay the amount of such lien or encumbrance and pursue recovery actions against Contractor, and (d) retain out of the amount withheld an amount sufficient to compensate Owner for its expenses (including actual attorney’s fees) in the matter.

6.4.3 Contractor hereby subordinates any mechanics’ and materialmen’s liens or other claims or encumbrances that may be brought by Contractor against any or all of the Work, the Facility, or the Job Site to any liens granted in favor of the Lenders, whether such lien in favor of the Lenders is created, attached or perfected prior to or after any such liens, claims or encumbrances, and shall use commercially reasonable efforts to require its Subcontractors to

 

45


Execution Version

 

similarly subordinate their lien, claim and encumbrance rights. Contractor agrees to comply with reasonable requests of Owner for supporting documentation required by the Lenders in connection with such subordination, including any necessary lien subordination and other agreements and the filing of necessary documentation to effectuate such subordination. Nothing in this Section 6.4.3 shall be construed as a limitation on or waiver by Contractor of any of its rights under applicable Law to file a lien or claim or otherwise encumber the Facility as security for any undisputed payments owed to it by Owner hereunder which are past due; provided that such lien, claim or encumbrance shall be subordinate to any liens granted in favor of the Lenders.

 

6.5

DEFICIENT REQUESTS FOR PAYMENT.

Should Owner and the Lenders believe any Request for Payment is non-conforming (by being incomplete or inaccurate or by not otherwise satisfying the requirements for a Request for Payment hereunder), Owner shall have the right, in its sole discretion, to (a) request additional information with respect to such non-conforming Request for Payment or (b) reject the nonconforming portion of a Request for Payment, but pay the undisputed portion in accordance with this Agreement. It is understood and agreed by the Parties that any Request for Payment which is non-conforming, to the extent of such non-conformance, shall not constitute a valid and proper Request for Payment, and Owner shall not be obligated to make payment of any disputed amounts related to such non-conformance until Contractor revises the Request for Payment or submits a Request for Payment in proper form.

 

6.6

OWNER PAYMENT OBLIGATIONS.

Owner shall review each Request for Payment and may make such exceptions in accordance with the terms of this Agreement. Not later than forty-five (45) Days after its receipt of a Request for Payment and supporting documentation in the manner, with such detail and at the time herein required, Owner shall make payment to Contractor in the amount required, less (i) any disputed portion of such Request for Payment, (ii) any undisputed amounts payable by Contractor to Owner hereunder from the immediately preceding billing period, and (iii) any other Owner withholding rights explicitly set forth herein. Owner shall make payment of the net amount specified in each Request for Payment submitted in accordance with Section 6.2, less (i) any disputed portion of such Request for Payment, (ii) any undisputed amounts payable by Contractor to Owner hereunder from the immediately preceding billing period, and (iii) any other Owner withholding rights explicitly set forth herein, not later than the last Business Day of the month immediately following the month in which such Request for Payment was received by Owner; provided, however, that if Contractor submits such Request for Payment to Owner after the 15th day of the relevant month, the time period within which Owner shall be obligated to make payment hereunder shall be extended by such number of days following such 15th day for which such Request for Payment was not submitted. See Exhibit B-5 for an example of such payment procedures.

 

6.7

FINAL PAYMENT.

Within thirty (30) days of the Final Completion Date, Contractor shall submit a final Monthly Progress Report and a final request for payment which shall set forth all amounts due and remaining unpaid to it (the “Final Request for Payment”), and upon approval thereof by Owner,

 

46


Execution Version

 

Owner shall pay to Contractor the amount due under such Final Request for Payment. Together with the submission of the Final Request for Payment to Owner, Contractor shall: (a) furnish Owner a Clear Lien and Privilege Certificate pursuant to Section 3.8.58; (b) deliver evidence satisfactory to Owner that Contractor has filed a request for cancellation of the Notice of Contract pursuant to Section 3.8.59, and (c) deliver evidence satisfactory to Owner, including a Payment Status Affidavit from Contractor and all Major Subcontractors in the form of Exhibit F-15 and Exhibit F-16, respectively, and a release and waiver of liens from Contractor and all Major Subcontractors in the form of Exhibit F-3 and Exhibit F-4, respectively, that all claims, liens, security interests or encumbrances in the nature of mechanics’, labor or materialmen’s liens or otherwise, arising out of or in connection with the Facility, Job Site or the performance by Contractor, or any Major Subcontractor, of the Work, have been satisfied or discharged.

 

6.8

OWNER’S RIGHT TO WITHHOLD PAYMENT.

6.8.1 Notwithstanding anything to the contrary contained herein, upon the occurrence and continuance of any of the following events, Owner, upon Notice to Contractor, may withhold or retain such portion (including all) of any payment due to Contractor under this Agreement as reasonably necessary to ensure the performance of the Work or to protect fully Owner’s rights hereunder:

(a) Contractor is in default under Section 31.1, but excluding (i) defaults for which the payment of liquidated damages is the sole and exclusive remedy as provided in Article 22, and (ii) costs attributable to any such default that are otherwise Direct Costs as provided in Exhibit B-1;

(b) there exists any outstanding and unpaid payment obligation owing by Contractor to Owner;

(c) provided that Contractor is then obligated to indemnify Owner for Indemnified Liens, (i) Contractor is not able to indemnify Owner to Owner’s satisfaction against any such lien that shall be registered against the Job Site, Facility (or any portion thereof), any Materials, any land or improvements pertinent thereto and such Indemnified Lien shall remain undischarged or (ii) Contractor, Owner or the Lenders shall have received any claims for Indemnified Liens arising in connection with this Agreement which have not been withdrawn, all arising as a result of any acts or omission of Contractor or any Subcontractors;

(d) Owner is required in accordance with applicable Laws to withhold Taxes payable by Contractor in respect of the Work;

(e) there is an assessment of any fines or penalties against Owner as a result of Contractor’s failure to comply with applicable Law, Permits or Applicable Codes and Standards;

(f) Contractor has failed to make payments to Subcontractors as required under their respective Subcontracts, excluding the right of Contractor to withhold payments to Subcontractors as provided under the terms of the applicable Subcontract; or

 

47


Execution Version

 

(g) Owner has incurred any other Non-Reimbursable Costs or liabilities for which Contractor is responsible hereunder.

6.8.2 Owner’s right to withhold amounts pursuant to this Section 6.8 shall not be deemed to in any way reduce Owner’s rights to withhold amounts due to Contractor under any other Section hereof. If Owner withholds amounts pursuant to this Section 6.8, Owner shall promptly inform Contractor of the reason therefor and once Contractor has corrected the reasons for the withholding, Owner shall pay the said withheld amount with the next Request for Payment submitted by Contractor. Notwithstanding anything to the contrary contained herein, Contractor shall not have any rights of termination or suspension as a result of Owner’s exercise of its rights under this Section 6.8.

 

6.9

RELEASE OF LIABILITY.

Acceptance by Contractor of payment pursuant to a Final Request for Payment shall constitute a satisfaction and release by Contractor and each of its Subcontractors in favor of Owner, Owner’s Representative, the Lenders, the Independent Engineer and all Affiliates, officers, directors, employees and agents thereof from all claims and liability hereunder with respect to the Work, or for any act or omission of Owner or of any of the above-listed Persons relating to or affecting this Agreement, except for (a) claims which are the subject of a Dispute filed by either Owner or Contractor prior to the date of such payment pursuant to Article 36, (b) Owner’s indemnity obligations hereunder, (c) any payment that may become due to Contractor under the last sentence of Section 6.7, or (d) any other provision hereof that is expressly intended to survive. Subject to acceptance of the Facility by Owner upon the Facility Substantial Completion Date, no payment shall: (i) be deemed a representation that Owner has inspected the Materials or the Work, (ii) constitute or be deemed an acceptance, in whole or in part, of any portion of the Work or (iii) operate to release Contractor from any obligations or liabilities hereunder.

 

7.

SCHEDULE BONUSES.

 

7.1

INTERIM MILESTONE BONUSES.

7.1.1 In consideration for Contractor’s timely completion of the Work, Owner will, subject to Section 7.4, pay to Contractor, not later than [***] following the date of achievement, in addition to the amounts payable to Contractor pursuant to Section 6.3, an Interim Milestone Bonus in respect of each corresponding Interim Milestone that Contractor has achieved prior to, on, or [***] following the relevant Completion Date.

7.1.2 If Contractor achieves an Interim Milestone (for Interim Milestones 2 through 16) prior to the relevant Completion Date, the amount of the Interim Milestone Bonus payable in respect of such Interim Milestone shall be increased by an amount equal to [***] for each day between the date of such achievement and such Completion Date.

7.1.3 If Contractor achieves an Interim Milestone after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Interim Milestone Bonus payable in respect of such Interim Milestone shall be equal to [***]. If Contractor achieves an Interim Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of

 

48


Execution Version

 

the Interim Milestone Bonus payable in respect of such Interim Milestone shall be equal to [***]. If Contractor achieves an Interim Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Interim Milestone Bonus payable in respect of such Interim Milestone shall be equal to [***]. For the avoidance of doubt, if Contractor does not achieve an Interim Milestone within [***] Days of the relevant Completion Date, no Interim Milestone Bonus shall be payable in respect of such Interim Milestone.

 

7.2

PRIMARY MILESTONE BONUSES.

7.2.1 In consideration for Contractor’s timely completion of the Work, Owner will, subject to Section 7.4, pay to Contractor, not later than [***] days following the Final Completion Date, in addition to the amounts payable to Contractor pursuant to Section 6.3, a Primary Milestone Bonus in respect of each corresponding Primary Milestone that Contractor has achieved prior to, on, or within [***] Days following the relevant Completion Date.

7.2.2 If Contractor achieves a Primary Milestone prior to the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be increased by an amount equal to [***] for each day between the date of such achievement and such Completion Date.

7.2.3 If Contractor achieves a Primary Milestone after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. If Contractor achieves a Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Primary Milestone Bonus payable in respect of such Primary Milestone shall be equal to [***]. For the avoidance of doubt, if Contractor does not achieve a Primary Milestone within [***] Days of the relevant Completion Date, no Primary Milestone Bonus shall be payable in respect of such Primary Milestone.

 

7.3

SUPER PRIMARY MILESTONE BONUSES.

7.3.1 In consideration for Contractor’s timely completion of the Work, Owner will, subject to Section 7.4, pay to Contractor, not later than [***] days following the Final

 

49


Execution Version

 

Completion Date, in addition to the amounts payable to Contractor pursuant to Section 6.3, a Super Primary Milestone Bonus in respect of each corresponding Super Primary Milestone that Contractor has achieved prior to, on, or within [***] Days following the relevant Completion Date.

7.3.2 If Contractor achieves a Super Primary Milestone prior to the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be increased by an amount equal to [***] for each day between the date of such achievement and such Completion Date.

7.3.3 If Contractor achieves a Super Primary Milestone after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. If Contractor achieves a Super Primary Milestone more than [***] Days after the relevant Completion Date but within [***] Days of the relevant Completion Date, the amount of the Super Primary Milestone Bonus payable in respect of such Super Primary Milestone shall be equal to [***]. For the avoidance of doubt, if Contractor does not achieve a Super Primary Milestone within [***] Days of the relevant Completion Date, no Super Primary Milestone Bonus shall be payable in respect of such Super Primary Milestone.

 

7.4

LIMITATIONS.

7.4.1 Owner’s total liability to Contractor under this Article 7 shall not exceed the Schedule Bonus Cap.

7.4.2 Notwithstanding anything contained herein to the contrary, if at any time Contractor’s Margin is reduced pursuant to Section 8.2 to:

(a) [***], then the aggregate amount of all Schedule Bonuses in respect of which Contractor has been paid or is entitled to be paid shall be reduced by an amount equal to [***] of such aggregate amount;

(b) [***], then the aggregate amount of all Schedule Bonuses in respect of which Contractor has been paid or is entitled to be paid shall be reduced by an amount equal to [***] of such aggregate amount; or

 

50


Execution Version

 

(c) [***], then the aggregate amount of all Schedule Bonuses in respect of which Contractor has been paid or is entitled to be paid shall be reduced by an amount equal to [***] of such aggregate amount;

provided that, for the avoidance of doubt, the reductions described in this Section 7.4.2 shall not be cumulative. If Owner has paid any Schedule Bonus(es) to Contractor prior to such reduction, then Owner may, without prejudice to Section 41.7, deduct from any amounts owed to Contractor hereunder an amount equal to the amount of such reduction.

7.4.3 Notwithstanding anything contained herein to the contrary, if Owner determines in its reasonable discretion that Contractor has not or will not be entitled to payment for any Primary Milestone or Super Primary Milestone pursuant to and in accordance with Section 7.2 and Section 7.3, respectively, Owner shall have no obligation to pay to Contractor any Schedule Bonuses pursuant to this Agreement. If Owner has paid any Schedule Bonus(es) to Contractor prior to such determination, then Owner may, without prejudice to Section 41.7, deduct from any amounts owed to Contractor hereunder an amount equal to the aggregate amount of all such Schedule Bonuses previously paid.

7.4.4 For the avoidance of doubt, Contractor shall not be entitled to payment in respect of any Schedule Bonus unless and until the achievement of the relevant Schedule Milestone is confirmed by a Certificate of Schedule Milestone Achievement to be provided by Contractor together with the relevant Request for Payment.

 

8.

COST OVERRUN; COST SAVINGS.

 

8.1

TOTAL COSTS.

8.1.1 Contractor acknowledges and understands that Owner has structured its Financing on the basis of the Target Price and is relying on the accuracy and sufficiency of the Target Price. Accordingly, Contractor agrees as a consequence that the Contractor’s Margin shall be subject to adjustment under the circumstances described in this Article 8, without impacting Owner’s obligation to reimburse Contractor for Direct Costs incurred by it in accordance with this Agreement.

8.1.2 For the purposes of this Agreement, “Total Costs” means, as of any date, an amount equal to the sum, as calculated by Owner pursuant to Section 8.2.3, of: (a) the Reimbursable Costs, Contractor’s G&A and Contractor’s Margin duly paid to Contractor by Owner pursuant to Section 6.2; (b) any costs incurred by Owner to perform portions of the Work or any other Contractor obligation that should have been performed by Contractor under this Agreement that are in excess of the amount that Owner would have paid to Contractor to perform such portions of the Work; and (c) any other cost which is expressly identified herein as being included in the calculation of Total Costs hereunder; provided that the Total Costs shall not include the Total Cost Exclusions. For the avoidance of doubt, the calculation of the Total Costs as of the Final Completion Date shall include all such amounts owing, but not yet paid, to Contractor with respect to the Work performed through and including the Final Completion Date, including amounts set forth in the Final Request for Payment.

 

51


Execution Version

 

8.2

COST OVERRUN.

8.2.1 In the event that at any time a Cost Overrun exists that is greater than [***], Owner shall be permitted by written notice to Contractor to reduce the Contractor’s Margin for all purposes hereunder as follows:

(a) if the Cost Overrun is greater than [***], but less than or equal to [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***];

(b) if the Cost Overrun is greater than [***], but less than or equal to [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***]; or

(c) if the Cost Overrun is greater than [***], the Contractor’s Margin shall be reduced by applying a Margin Percentage of [***].

8.2.2 Owner shall be permitted to reduce the Contractor’s Margin pursuant to Section 8.2.1 more than once if following Owner’s first delivery of a notice pursuant to Section 8.2.1 a Cost Overrun increases to exceed the next then applicable threshold set forth therein. Each reduction of Contractor’s Margin effected pursuant to Section 8.2.1 shall be applied both retroactively and prospectively, and all payments by Owner of Contractor’s Margin made prior to such reduction shall be retroactively adjusted to be equal to an amount calculated using the reduced Contractor’s Margin. In such event, without prejudice to Section 41.7, Owner may deduct from any amounts owed to Contractor hereunder an amount equal to the positive difference between the amount of the Contractor’s Margin previously paid to Contractor pursuant to Section 6.2 calculated using the previously applicable Contractor’s Margin and the amount of the Contractor’s Margin previously paid to Contractor as recalculated using the reduced Contractor’s Margin. Each notice delivered by Owner pursuant to Section 8.2.1 shall include Owner’s supporting calculations of the amount of the relevant Cost Overrun and, if applicable, the amount of such positive difference to be deducted from amounts owed to Contractor.

8.2.3 Within [***] days following the Final Completion Date, Owner shall calculate and deliver to Contractor written notice of the amount by which the Total Costs exceed the Target Price, if any, as of the Final Completion Date, such notice to include Owner’s supporting calculations of the amount of such excess.

8.2.4 The Parties acknowledge and agree that the remedies set forth in this Section 8.2 (a) are reasonable and appropriate measures of the damages for the circumstances described herein and do not represent a penalty, and (b) constitute Owner’s sole remedies for the Total Costs exceeding the Target Price.

 

52


Execution Version

 

8.3 COST SAVINGS.

8.3.1 Within thirty (30) days following the Final Completion Date, Owner shall calculate and deliver to Contractor written notice of the Cost Savings, if any, such notice to include Owner’s supporting calculations of the amount of the Cost Savings. The Cost Savings shall be calculated as of the Final Completion Date. If there is a Cost Savings that is greater than [***], Owner shall make payment of the following amount to Contractor within fifteen (15) days of Owner’s delivery of written notice to Contractor:

(a) if the Cost Savings is greater than [***], but less than or equal to [***], an amount equal to [***] of the amount of the Cost Savings;

(b) if the Cost Savings is greater than [***], but less than or equal to [***], an amount equal to [***] of the amount of the Cost Savings; and

(c) if the Cost Savings is greater than [***], an amount equal to [***] of the amount of the Cost Savings.

 

9.

PERFORMANCE SECURITY.

 

9.1

TYPES OF PERFORMANCE SECURITY.

To secure Contractor’s performance of its obligations hereunder, Contractor acknowledges and agrees that Owner shall have the right to hold (a) the Performance and Payment Bonds, and (b) the Contractor Guarantee.

 

9.2

PERFORMANCE AND PAYMENT BONDS.

9.2.1 On or prior to the Notice to Proceed Date, Contractor shall deliver to Owner a performance bond (in the form of a bank letter of credit as provided in Exhibit F-9A) and a payment bond (in the form of an insurance surety bond as provided in Exhibit F-9B) issued for the benefit of Owner (the “Performance and Payment Bonds”), in each case issued by a Qualified Surety.

9.2.2 The Performance Bond shall constitute security for all of Contractor’s payment and performance obligations hereunder. The Performance Bond shall have a face amount equal to a variable percentage of the then-current Target Price, as follows: (i) as of the Notice to Proceed Date, the face amount of the Payment Bond shall be equal to [***] of the then-current Target Price; (ii) on the date that is [***] days following the Notice to Proceed Date, the face amount of the Payment Bond shall be increased to be equal to [***] of the then-current Target Price; and (iii) on the Facility Substantial Completion Date, the face amount of the Payment Bond shall be decreased to be equal to [***] of the then-current Target Price. In the event the Target Price is increased or decreased by one or more Change Orders or otherwise in an aggregate amount equal to or greater than [***] in accordance with the terms of this Agreement prior to the Facility Substantial Completion Date, Contractor shall increase or decrease the amount of the Performance Bond to reflect the corresponding increase or

 

53


Execution Version

 

decrease in the Target Price by [***] of such increase or decrease, within [***] Business Days of such increase or decrease in the Target Price. The Performance Bond will be reduced in value by [***] upon Facility Substantial Completion, which may then be held by Owner until the expiration of the Warranty Period.

9.2.3 The Payment Bond shall constitute security for the payments made by Owner to Contractor on or after the Notice to Proceed Date. The Payment Bond shall have a face amount equal to a variable percentage of the initial Target Price, as follows: (i) as of the Notice to Proceed Date, the face amount of the Payment Bond shall be equal to [***] of the then-current Target Price; (ii) on the date that is [***] days following the Notice to Proceed Date, the face amount of the Payment Bond shall be increased to be equal to [***] of the then-current Target Price; (iii) on the LPS1 Substantial Completion Date, the face amount of the Payment Bond shall be decreased to be equal to [***] of the then-current Target Price; and (iv) on the LPS3 Substantial Completion Date, the face amount of the Payment Bond shall be decreased to be equal to [***] of the then-current Target Price. The Payment Bond will be held by Owner until the Facility Substantial Completion Date.

9.2.4 In the event amounts are due under this Agreement from Contractor to Owner (including Schedule Delay Liquidated Damages), and such amounts are not paid by Contractor when due, Owner shall have the right to draw amounts under the Performance Security equal to the amount owing by Contractor.

9.2.5 If at any time the surety that has issued the Performance and Payment Bonds is no longer a Qualified Surety, then Contractor shall replace such Performance and Payment Bonds with a replacement instrument complying with the terms hereof from a Qualified Surety within [***] Business Days from receiving notice from Owner.

 

9.3

CONTRACTOR GUARANTEES.

9.3.1 On the Effective Date, Contractor shall deliver an executed Contractor Guarantee to Owner. Contractor shall cause the Contractor Guarantee to remain in full force and effect until the expiration of the Warranty Period. Contractor acknowledges that Owner shall have the right, in its sole discretion, to issue demands for payment under the Contractor Guarantee.

9.3.2 As soon as available, but in any event no later than [***] Days after the end of each applicable six (6) month period, Contractor or the Contractor Guarantor shall deliver to Owner a copy of the audited consolidated balance sheets at the end of each such period as well as the related consolidated statements of income, retained earnings, and cash flows for such period. All financial statements delivered pursuant to this Section 9.3 shall be complete and correct in all material respects and shall be prepared in accordance with A-IFRS applied consistently throughout the periods reflected therein. If the Contractor Guarantor makes the foregoing financial statements publicly available on its website or through filings pursuant to applicable securities laws, then the requirements of this Section 9.3 shall be deemed met by the Contractor Guarantor making such financial statements publicly available in accordance with the requirements of applicable securities laws or, otherwise, in accordance with its customary practice.

 

54


Execution Version

 

10.

QUALITY CONTROL AND INSPECTION.

 

10.1

QUALITY MANAGEMENT PLAN.

Within thirty (30) Days after the Effective Date, and prior to commencing any aspect of the Work, Contractor shall have submitted for Owner’s review and approval, and Owner shall have approved, as being in accordance with Owner Standards, a formal program for inspecting and testing all aspects of the Work (the “Quality Management Plan”). Owner shall have a period of thirty (30) Days following submittal to it of the Quality Management Plan to approve or comment upon the Quality Management Plan. If Owner approves the Quality Management Plan, or Owner does not approve or provide comments on the Quality Management Plan within such thirty (30) Day period, then Contractor may proceed to implement such Quality Management Plan; provided, however, that Owner may at any time require Contractor to amend the Quality Management Plan if it is not in accordance with the requirements of this Agreement. The individual(s) responsible for implementing the Quality Management Plan shall be identified by Contractor to Owner.

 

10.2

DEFECTS AND DEFICIENCIES.

10.2.1 Contractor shall perform, or cause to be performed, quality control and inspection activities related to the Work as required by the Contractor’s Quality Management Plan, this Agreement and Owner Standards. Prior to entering any purchase orders for Materials or any Subcontracts, Contractor shall provide Owner the quality control and inspection program for such Subcontractor, and Contractor shall (i) ensure that each such program is substantially the same as the approved Quality Management Plan, and (ii) require each such Subcontractor to provide periodic reports and maintain accurate and ongoing records showing compliance with each such quality control and inspection program. The Quality Management Plan must be adequate to meet the quality control and inspection needs of the Work, and Contractor may not rely upon Owner or any other Person or Government Authority to provide such services. Contractor shall inspect and test the Work, including all design, engineering, installation, Materials, tools and supplies performed or provided. All Defects or Deficiencies identified by such inspection or testing shall be included in the Monthly Progress Report submitted to Owner with the Contractor’s Request for Payment. The Monthly Progress Report shall describe in detail (a) all such Defects or Deficiencies identified, including a failure analysis of the problem, (b) a description of the solutions identified for each such Defect and Deficiency, (c) all Work that was re-performed or corrected and any related services rendered during the immediately preceding month, and (d) all such Defects or Deficiencies not then corrected or re-performed. Contractor shall identify a solution for each such Defect and Deficiency as soon as possible, but in any event not later than seven (7) days after the date that such Defect and Deficiency is identified, and, in the case of known defects or deficiencies in Owner Furnished Equipment and Materials, notify and request a solution from Owner or Owner Contractors.

10.2.2 Contractor shall correct, or cause to be corrected, all Defects and Deficiencies as soon as practicable under the circumstances, and shall correct, or cause to be corrected, (a) any Defects or Deficiencies identified during the design process prior to the date that the procurement process begins, (b) any Defects or Deficiencies identified during the procurement process prior to the date that the shipping of Materials and equipment begins, (c) any Defects or Deficiencies identified during the performance of the Work prior to the start of the Demonstration Tests, (d)

 

55


Execution Version

 

any Defects identified during the Demonstration Tests prior to the start of the Performance Tests (excluding Punch List Items), and (e) any Defects or Deficiencies identified during the Performance Tests prior to re-running the Performance Tests (excluding Punch List Items); provided that with respect to clauses (a) through (e) above, Contractor shall have the right, upon prior written notice to Owner, to re-sequence the Work (including not correcting the Defects in the order required by this Section 10.2.2) as necessary to correct such Defects or Deficiencies as efficiently and expeditiously as possible.

 

10.3

INSPECTION RIGHTS.

Owner and the Owner Designees shall have the right to inspect in accordance with Owner Standards all Work performed in accordance with this Agreement and any item of Materials, service or workmanship to be provided in accordance with this Agreement as and to the extent described in Exhibit A or referred to elsewhere herein, and Contractor shall arrange such inspection, at the request of Owner, at any location that Work is performed or where Materials are fabricated or stored. With respect to tests which Contractor is required to perform hereunder pursuant to Exhibit A or Exhibit R, whether the tests take place at Contractor’s factory, or at the factory of a Subcontractor, or the Job Site, Contractor shall supply all necessary labor, materials, equipment, apparatuses, instruments and competent test personnel who shall be able to take complete charge of the tests, and shall be authorized to represent and make decisions for the proper carrying out of the tests; provided, however, that with respect to any test set forth in Exhibit A or Exhibit R which Owner or the Owner Designees are entitled to witness, Contractor shall not be required to re-perform such test by virtue of Owner’s or the Owner Designees’ failure to observe same if Owner shall have been given at least fifteen (15) Days’ notice thereof (except for routine in process inspections). Owner shall at any time have the right to reject, or to direct Contractor to reject, any such portion of the Work, including any design, engineering, Materials, installation, tools or supplies, which in Owner’s reasonable judgment do not conform to the provisions hereof, including the requirements set forth in Exhibit A and the Drawings and Specifications, or which contain Defects or Deficiencies. Upon such rejection, Contractor shall as soon as practicable under the circumstances, but in no case later than the commencement of the Performance Tests, remedy any such condition identified by Owner as giving rise to such rejection. In the case of discovered defects or deficiencies in Owner Furnished Equipment or Material, Contractor shall promptly notify Owner. Copies of all test certificates, performance curves and data sheets required by Owner shall be supplied by Contractor to Owner’s Representative in reproducible form. Sufficient information is to be given on all test certificates, performance curves and data sheets to enable the Materials to which they refer to be identified.

 

10.4

THIRD PARTY INSPECTION.

Contractor understands that the Owner Designees or the Lenders, and certain Government Authorities have or shall have the right, from time to time, to observe and inspect the Work and the Facility and to observe all tests of the Work and the Facility. Contractor shall allow such third-party inspectors access to the Work and the Facility and, upon execution by a third-party (excluding Government Authorities) of a confidentiality agreement with Contractor, to the Contractor’s technical and design records pertaining thereto, so long as either Owner’s Representative is present or Contractor has obtained the prior written approval of Owner. Owner agrees to protect as confidential anything designated by Contractor as such, whether by notation

 

56


Execution Version

 

thereon or separate Notice; provided that in no event shall Owner be liable to Contractor for the failure of any party (other than Owner) to comply with the confidentiality requirements of Contractor.

 

10.5

EFFECT OF WAIVER OF INSPECTION RIGHTS.

In the event that Owner or the Owner Designees shall waive or fail to exercise their right to test and inspect as herein provided, such waiver or failure shall in no way relieve Contractor of its obligations to perform the Work, or any part of it, in accordance with this Agreement, nor shall such waiver or failure prejudice or affect the rights of Owner or the Owner Designees set forth herein; nor shall any test or inspection by Owner, any Lenders or the Owner Designees or any failure to test or inspect be construed as an approval or acceptance of the Work or any part thereof. However, if any test or inspection is otherwise successful, the failure of any or all of Owner or the Owner Designees to attend such test or inspection shall not alter the successful nature of the test or inspection; provided, however, that Contractor shall promptly provide to Owner detailed information of the test or inspection, including the information specified in Section 10.3.

 

11.

HEALTH, SAFETY, SECURITY AND ENVIRONMENT

 

11.1

COMPLIANCE.

Contractor shall be a “prime contractor” for all purposes under the Occupational Safety and Health Act of 1970 and shall take all actions necessary or advisable to ensure compliance with OSHA regulations and the health and safety of all persons at the Job Site, or portion thereof, until the earlier of (a) Owner’s issuance of written notice that Owner will assume the role of prime contractor for the Job Site, or such area or areas within the Job Site as specified in such notice, and (b) the termination of this Agreement.

 

11.2

HSSE PROGRAM.

11.2.1 Within sixty (60) Days after the Effective Date, and prior to commencing any aspect of the Work, Contractor shall have submitted for Owner’s review and approval, and Owner shall have approved, as being in accordance with Owner Standards and Exhibit U, a formal health, safety, security and environment program (the “HSSE Program”). Owner shall have a period of thirty (30) Days following submittal to it of the HSSE Program to approve or comment upon the HSSE Program. If Owner approves the HSSE Program, or Owner does not approve or provide comments on the HSSE Program within such thirty (30) Day period, then Contractor may proceed to implement such HSSE Program; provided, however, that Owner may at any time require Contractor to amend the HSSE Program if it is not in accordance with the requirements of this Agreement, including those set forth in Exhibit U. The individual(s) responsible for implementing the HSSE Program shall be identified by Contractor to Owner. Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work in accordance with applicable Law, the Contractor’s safety procedures and Owner Standards.

11.2.2 Contractor shall provide sufficient supervision for health, safety, security and environmental protection (“HSSE”) and take all precautions necessary to provide all protection to prevent damage, injury or loss to (a) all employees engaged in connection with the Work and all

 

57


Execution Version

 

other Persons who may be affected thereby, (b) all the Work and all Materials to be incorporated therein, whether in storage on or off the Job Site, under the care, custody or control of Contractor or any Subcontractors, (c) other property at the Job Site or adjacent thereto or the access route to the Job Site, including trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction or (d) the environment (except as otherwise permitted under any Permit).

 

11.3

SAFEGUARDS.

Contractor shall erect and maintain, as required by existing conditions and progress of the Work, all HSSE-related safeguards, including physical barriers, fences and railings. Contractor shall post danger signs and other warnings against hazards, promulgate safety regulations and notify owners and users of adjacent utilities of any dangerous or hazardous conditions. In accordance with Laws, Permits, Applicable Codes and Standards, and Owner Standards, Contractor shall exercise the utmost care in the use and handling of explosives or other Hazardous Substances or equipment and only competent, trained and experienced employees of Contractor or of any Subcontractor shall be permitted to handle such explosives or other Hazardous Substances or equipment. All warning signs and notices shall be in English, Spanish and such other language as appropriate so that the safety communications will be understood by all personnel.

 

11.4

HSSE INCIDENTS.

Contractor shall have the following HSSE incident and near miss reporting obligations:

11.4.1 Contractor shall report in writing to Owner (and, to the extent required by any applicable Law, Applicable Codes and Standards or applicable Permit, the appropriate Government Authority) details of any HSSE-related incident that occurs on or in the vicinity of the Job Site as soon as possible after its occurrence, but in any event no later than twenty-four (24) hours after such HSSE-related incident occurs. In the case of any fatality or Severe Injury, Contractor shall immediately (a) notify Owner (and, to the extent required by any applicable Law, Applicable Codes and Standards or Permits, the appropriate Government Authority), (b) stop all Work on or in the vicinity of the Job Site, (c) and schedule a meeting as soon as practical (but no later than twenty-four (24) hours after the occurrence of such fatality or Severe Injury) with Owner to review the incident and, if necessary and/or required by Owner, revise the Contractor’s HSSE precautions and programs. Following any meetings with Owner pursuant to this Section 11.4.1, Contractor shall implement all revisions to the Contractor’s safety precautions and programs as required by Owner, and upon Notice from Owner, Contractor shall recommence the performance of the Work. Contractor shall initiate incident investigations as soon as practical (but no later than forty-eight (48) hours after the occurrence of such HSSE-related incident). Owner shall be invited to participate in all investigations, and may elect to be an active participant in any investigation and reserves the right to perform a parallel investigation. Contractor shall promptly send Owner copies of all citations issued by a Government Authority against Contractor resulting from or relating to an incident while performing the Work. Contractor shall report any HSSE-related incident and near misses at weekly HSSE meetings for review and discussion. Any delays in, or additional costs incurred in connection with, the Work resulting from the Contractor’s compliance with this Section 11.4.1 shall not form the basis for a Change Order.

 

58


Execution Version

 

11.4.2 In the event of any emergency situation that endangers or could endanger life, property or the environment, Contractor shall take such action as may be reasonable and necessary to prevent, avoid or mitigate injury, damage or loss and shall, as soon as possible, report any such incidents, including the Contractor’s response and actions with respect thereto, to Owner.

11.4.3 Whenever Owner shall, in its sole discretion, determine that such an emergency situation exists, or is imminent, with respect to any part or all of the Work or other activities on the Job Site, Owner shall have the right to occupy and control the Job Site and, should Owner deem it necessary, to modify any aspect of the Work related to such emergency situation including stopping or altering the Work.

 

12.

CHANGES IN THE WORK.

 

12.1

GENERAL.

12.1.1 Owner may at any time order changes to the Work. Contractor may propose changes to the Work for Owner’s consideration; provided that Owner shall not be obligated to approve any such change. Contractor shall be entitled to receive a Change Order in accordance with the provisions of Section 12.1.2 with respect to: (a) Force Majeure Events; (b) Owner Caused Delays; (c) Owner-directed or approved changes; (d) any error, inaccuracy or omission in or change by Owner to the Relied Upon Information that demonstrably and adversely affects Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule; (e) as provided elsewhere in this Agreement including in Sections 12.4 and 16.3.2; (f) Pre-Existing Hazardous Substances which demonstrably and adversely impact Contractor’s costs and/or ability to perform the Work in accordance with the Project Schedule (except to the extent any additional costs or delay is the result of Contractor’s, its Subcontractors’ Grossly Negligent act or omission or willful misconduct in the handling, storage or transportation of any Pre-Existing Hazardous Substance after discovery by Contractor, a Subcontractor); (g) suspensions in the Work in accordance with Section 17.1.1 or Section 17.1.2; (h) any Change in Law that increases the Direct Costs of the Work by more than [***]; provided that, (1) with respect BH Testing Delay, the Change Order which shall be limited to a day-for-day extension of the applicable LNG Production System Substantial Completion Date or the Facility Substantial Completion Date, as the case may be, equal to the number of days of such BH Testing Delay, and (2) adjustments may be made to a Completion Date only as a result of an Owner Caused Delay, which shall be subject to the restrictions set forth in Appendix 2 of Exhibit D.

12.1.2 Contractor shall be entitled to receive only one Change Order with respect to the same act or event and shall not be entitled to aggregate the cumulative impact of such act or event or two or more acts or events. Unless a particular activity is demonstrated to adversely impact (a) the Critical Path, and (b) an LNG Production System Substantial Completion Deadline or the Facility Substantial Completion Deadline, no adjustment to such LNG Production System Substantial Completion Deadline or Facility Substantial Completion Deadline, as applicable, shall be made, and any adjustments to the Project Schedule made in connection with a Change Order shall take into account any available float for such activity that is affected by an Owner Caused Delay, and with respect to a Force Majeure Event or any other basis for a Change Order, as applicable, shall preserve any available float if and to the extent such event or basis could not be avoided or mitigated by Contractor.

 

59


Execution Version

 

12.1.3 Except for Owner-directed changes under Section 12.3, all changes in the Work shall be authorized by a written Change Order executed by Owner and Contractor. Any such Change Order shall be accompanied by additional and/or revised Drawings and Specifications, as reasonably necessary, and shall be priced as provided in Section 12.2. All such changes shall be performed under and governed by the provisions hereof and the relevant Change Order. Contractor acknowledges and agrees that the Independent Engineer is not an agent of Owner and is not authorized to execute Change Orders on behalf of Owner.

12.1.4 Contractor agrees that any Change Order shall constitute the final and complete compensation and satisfaction for all costs and schedule effects related to (a) the implementation of the stated changes, (b) the cumulative impact of effects resulting from the stated changes on all prior Work and changes in the Work to be performed as scheduled, and (c) any costs associated with expediting the Work to mitigate the effect of any change or delay which costs shall be included in the Change Order. Contractor expressly waives any claims for additional compensation, damages or time extension in connection with the stated changes; provided, however, that if a Dispute exists with respect to any Change Order (whether proposed by Contractor or Owner), such Dispute shall be resolved pursuant to the dispute resolution provisions set forth in Article 36.

12.1.5 No Change Order shall be issued in connection with any Defects or Deficiencies on the part of Contractor or any Subcontractor in the performance of the Work hereunder.

12.1.6 No Change Order request by Contractor shall be permitted after the Final Request for Payment is submitted. The Parties shall not be bound to any changes to the Work or this Agreement unless expressly set forth in a Change Order that has been signed by both Parties (or solely by Owner under Section 12.3.1) or determined in accordance with the dispute resolution procedures set forth in Article 36.

12.1.7 Contractor shall not comply with any oral changes in the Work received from or on behalf of Owner.

12.1.8 Except as specifically set forth in a Change Order, no Change Order shall modify or affect: (a) the Work or the requirements set forth herein; (b) the Target Price; (c) the Project Schedule; (d) the Critical Path; (e) any Applicable Deadline, (f) the Demonstration Tests or the Performance Tests; or (g) any other right, liability or obligation of Contractor hereunder.

 

12.2

CHANGE ORDER PROCESS.

12.2.1 Contractor shall provide Notice to Owner as soon as practicable, but no later than five (5) Business Days, after the time when Contractor knows of the impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that will impact the Work. Failure to provide such Notice within five (5) Business Days after the time when Contractor knows of the impact of any Force Majeure Event shall be deemed to be a waiver of the Contractor’s right to receive a Change Order with respect thereto. Such Notice shall, to the extent practicable, specify the estimated impact on the Target Price and/or the Project Schedule, as applicable, the impact upon the various portions of the Work occasioned by reason of such Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, and shall substantiate the foregoing to the

 

60


Execution Version

 

satisfaction of Owner. In the event that Contractor does not know or is unable to specify with reasonable certainty the impact upon the Work at the time such Notice is to be delivered, Contractor shall instead provide Owner with a notice of a potential or anticipated impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that could impact the Work, and shall thereafter provide Owner (and, if requested by Owner, the Independent Engineer) with periodic supplemental Notices during the period that the Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable, continues, detailing any developments, progress or other relevant information of which Contractor is aware. To the extent Owner (in consultation with the Independent Engineer with respect to a Material Change) agrees with the Contractor’s determination of a Force Majeure Event or Owner Caused Delay or any other basis for a Change Order, as applicable, and the effects thereof, Owner shall notify Contractor of Owner’s acceptance. In the event Owner (in consultation with the Independent Engineer with respect to a Material Change) does not accept the Contractor’s findings, Owner or Contractor shall be permitted to dispute such Change Order in accordance with Article 36, and Contractor shall be paid for any Work performed in respect of such disputed Change Order as provided in Section 12.2.5. Notwithstanding the time requirements in this Section 12.2.1, Contractor shall have thirty (30) Days from the Effective Date or the date of receipt, whichever is later, to review Relied Upon Information and provide Notice to Owner of any changes to the Work (if any) arising therefrom. Subsequent to that initial review period, the time requirements of this Section 12.2.1 shall also apply to Relied Upon Information.

12.2.2 As soon as practicable, and in any event within fifteen (15) Days (or such other period as is mutually agreed by Owner and Contractor) after receipt from Owner of a request for a change or Notice of Owner’s acceptance under Section 12.2.1, Contractor shall submit to Owner a proposal for implementing the change indicating the estimated change to the Target Price and/or the Project Schedule, as applicable. If Owner (having consulted with the Independent Engineer in the case of a Material Change) agrees that the Contractor’s proposal should be implemented, Owner (having consulted with the Independent Engineer in the case of a Material Change) shall issue a Change Order incorporating such proposal, which shall then be signed by both parties as required by Section 12.1.3. Subject to Section 12.2.5, upon receiving such mutually signed Change Order, Contractor shall diligently perform the change in accordance with the terms thereof.

12.2.3 Contractor’s proposal required pursuant to Section 12.2.2 shall consist of: (a) a detailed material take-off with supporting calculations in accordance with the pricing structure herein, for pricing the change, (b) revisions, if any, to the Drawings and Specifications, (c) a schedule for the work associated with the proposed change, (d) the effect, if any, to the Target Price and/or the Project Schedule, as applicable, (e) the effect, if any, of the change on the Work, including the Performance Tests and/or Demonstration Tests (or protocol therefor), (f) changes, if any, to any right, liability or obligation of a Party or any other provision hereof, and (g) changes, if applicable, to any Applicable Deadline or Schedule Milestone Completion Date.

12.2.4 Contractor’s supporting calculations shall show: (a) the estimated unit quantities, home office and Job Site manpower, Material usage and services to be added and/or deducted by size, type and/or amount provided; (b) the industry estimating reference or other basis used to determine prices, man-hours per unit of installed Materials, rental rates and other similar cost standards; (c) detailed cost breakdown for manpower, engineering and Materials; (d) the Contractor’s Margin; and (e) impacts, if any, to the Critical Path.

 

61


Execution Version

 

12.2.5 Contractor shall not suspend performance of this Agreement during the review and negotiation of any change (regardless of whether such change is proposed by Contractor or Owner), except as may be directed by Owner. Contractor shall commence and perform the changed Work specified in the Change Order issued by Owner under Sections 12.2.2 or 12.3.1, on a cost-reimbursable basis, using Exhibit B-1 and Exhibit C as the basis for such compensation. In the event Owner and Contractor are unable to reach agreement for pricing of a change, or time for performance of changed Work, disagreements regarding such Change Order shall be subject to the dispute resolution procedures set forth in Article 36. Pending resolution of the Dispute, Contractor shall perform the Work as specified in such Change Order and Owner shall continue to pay Contractor all Direct Costs and Contractor’s G&A and Contractor’s Margin applicable thereto associated with such Change Order.

 

12.3

DISPUTED CHANGES.

12.3.1 If Owner (having consulted with the Independent Engineer in the case of a Material Change) disagrees in any way with any proposal of Contractor under Section 12.2, Owner may issue a Change Order to Contractor changing the Work and/or Project Schedule, which Change Order is executed solely by Owner, and Contractor shall be entitled to payment as set forth in Section 12.2.5 and the impact to the Target Price and/or the Project Schedule, as applicable, shall be resolved pursuant to the dispute resolution procedures set forth in Article 36.

12.3.2 Any Change Order executed solely by Owner shall be accompanied by the Contractor’s proposal marked to show Owner’s modifications thereto and shall order Contractor to implement the change in accordance with the proposal as modified by Owner.

 

12.4

CHANGES DUE TO UNKNOWN SUBSURFACE CONDITIONS.

12.4.1 Contractor shall be entitled to receive a Change Order to the extent that it encounters subsurface conditions including geotechnical conditions, archaeological artifacts, fossils, underground utilities or manmade structures which materially differ from, or were not disclosed or provided to Contractor by Owner in Exhibit M or the Geotechnical Reports or which were not identified by Contractor (or were not reasonably inferable or foreseeable) on the basis thereof, that (a) cannot be safely removed by heavy equipment present at the Job Site at no additional cost and without delay to Contractor, (b) are not Job Site Conditions, and (c) cause an increase in the cost to complete the Work or cause a delay in Contractor’s performance of any Critical Path activities, to the extent actually and demonstrably caused by the existence of such geotechnical conditions, archaeological artifacts, fossils, underground utilities or manmade structures.

12.4.2 In the event Contractor encounters any conditions listed in Section 12.4.1 at the Job Site, Contractor shall leave such sites untouched and protected by fencing and shall immediately stop any Work affecting the area. Contractor shall notify Owner of any such discovery as soon as practicable, and Contractor shall carry out Owner’s instructions for dealing with the same. Contractor shall prevent its personnel, its Subcontractors’ personnel and any other Persons from removing or damaging any such article or thing.

 

62


Execution Version

 

12.5

INFORMATION REQUESTS.

Owner may request that Contractor provide written information (prior to the issuance of a request for change) regarding the effect of a contemplated change on (a) the Work or the requirements set forth in Exhibit A, (b) the Target Price, (c) the Project Schedule, (d) the Critical Path, (e) any Applicable Deadline or Schedule Milestone Completion Date, if applicable, (f) the Demonstration Tests or Performance Tests or (g) any right, liability or obligation of Contractor hereunder. The purpose of such a request will be to determine whether or not a change will be requested. Contractor shall provide the requested information within fourteen (14) Days after the receipt of said request or alternatively inform Owner of the need for additional time to provide the requested information, which shall not exceed an additional fourteen (14) Days. Such an information request by Owner is not a Change Order and shall not be construed to authorize Contractor to commence performance of the contemplated change in the Work.

 

13.

PROJECT SCHEDULE AND MONTHLY PROGRESS REPORTS.

 

13.1

GENERAL.

Contractor shall prosecute the Work in accordance with or in advance of the Project Schedule; provided, however, that any failure of Contractor to adhere to the Project Schedule, for reasons which are not otherwise excused hereunder, shall not limit or otherwise reduce its obligations or liabilities hereunder.

 

13.2

PROJECT SCHEDULE.

13.2.1 Contractor shall develop, deliver and maintain the Project Schedule in accordance with Exhibit E. The Project Schedule shall be the reference schedule for the duration of the Work, and shall be in the form of Exhibit D.

13.2.2 Except as provided in Article 12 or otherwise expressly in accordance with Exhibits D and E, Contractor shall not make any alterations to the Project Schedule. During the performance of the Work, Contractor and Owner (including Owner’s Representative or his designee, and any other Persons designated by Owner, and the Contractor’s Key Personnel) shall, at a minimum, conduct meetings as provided in Exhibit E for the purpose of reviewing the progress of the Work, the latest Monthly Progress Report, the Quality Management Plan, the HSSE Program, the Contractor’s, Subcontractors’ adherence to the requirements set forth in Exhibit A, the Critical Path and the Project Schedule as well as the status of any claims on the Facility, the Job Site or the Work and claims submitted pursuant to the terms of this Agreement.

 

13.3

MONTHLY PROGRESS REPORTS.

Contractor shall prepare and submit a monthly report meeting the requirements of Exhibit I (each, a “Monthly Progress Report”) to Owner, Owner’s Representative and the Independent Engineer with each Request for Payment but in no event later than the tenth (10th) day of each month. Submission of Monthly Progress Reports shall continue until Contractor has completed all Work that is known to be outstanding at the time of Final Completion. Monthly Progress Reports shall include information relating to the performance of the Owner Contractors and the other information set forth in Exhibit I. The Parties agree that slippages in the Critical Path caused

 

63


Execution Version

 

by Contractor or its Subcontractors may be remedied by recovery plans and acceleration plans in accordance with Section 16.3, consisting of critical services, expediting of critical Material and equipment, the addition of productive construction equipment, additional competent supervision and other similar beneficial resources. It is further agreed that slippages in the Project Schedule known to Contractor will not be concealed from Owner, the Independent Engineer or the Lenders in the monthly reports.

 

14.

TRAINING.

Contractor shall be responsible for training Owner’s and/or its Affiliate’s regular operating personnel listed in Exhibit Q in accordance with Exhibit G. Training aids shall be provided by Contractor as required to adequately present the subject material. The general topics of the training will encompass reasonable information necessary for efficient and proper operation of each LNG Production System and the Facility, including operation, maintenance and repair. Training will consist of classroom, on-the job operational training and training using simulation software as necessary to comply with the requirements of this Article 14 and the requirements set forth in Exhibit A. Contractor shall design and submit an outline of a training program to Owner within one hundred eighty (180) Days after the Notice to Proceed Date and a detailed training program one hundred eighty (180) Days prior to commencement of training. Owner shall have a period of thirty (30) Days following submittal to it of the training program outline or detailed program to approve or comment upon each submittal. Contractor shall effect changes in response to Owner’s comments and resubmit the training procedures for Owner’s review and approval within fifteen (15) Days of receipt of such comments from Owner, and Owner shall have a further period of fifteen (15) Days following such resubmittal to approve. Contractor shall conduct at least one (1) full course of training prior to the start of any Pre-Commissioning activities. The training documentation and instruction shall be in the English language. All of the Contractor’s training personnel will speak fluent English as reasonably determined by Owner. All training provided by Contractor shall stress strict compliance with the operation and maintenance manuals, operating instructions, system checklists and/or procedures. If any of the Contractor’s training personnel repeatedly allow, encourage or demonstrate any attitudes or work practices that are not in strict compliance with the operation and maintenance manuals, operating instructions, system checklists and/or procedures, such training personnel shall be replaced by Contractor.

 

15.

TESTING.

 

15.1

FACTORY TESTS.

Contractor shall perform all customary or required factory tests of the Materials to the extent required by Exhibit A or Exhibit R or by Owner Standards. Contractor shall issue a test memorandum to Owner no later than thirty (30) Days prior to the commencement of each factory test, which memorandum shall describe the factory test to be performed, the applicable item of Material being tested, the standards and method of testing, and the testing facility’s capabilities and shall state a proposed test date. Owner’s Representative and the representative of the Independent Engineer shall be permitted to attend and participate in all such factory tests. Contractor shall provide the results of such required factory tests to Owner within ten (10) Days of the completion of each such factory test. Successful completion of such factory test shall be a precondition to shipment of the tested item of Material.

 

64


Execution Version

 

15.2

DEMONSTRATION TESTING.

15.2.1 Contractor shall submit Demonstration Test procedures and a level 3 Demonstration Test schedule at least sixty (60) Days before commencement of the Demonstration Tests in accordance with (and as defined in) Exhibit R. Prior to commencing any Demonstration Tests, Contractor shall submit to Owner a certification that the Facility is free of known Defects and Deficiencies and ready for performance of the Demonstration Tests in accordance with Exhibit R. Owner shall be given at least ten (10) Business Days’ prior Notice by Contractor of the commencement of any Demonstration Tests so that Owner can schedule its and/or its Affiliate’s personnel to witness such Demonstration Tests.

 

15.3

PERFORMANCE TESTING.

15.3.1 Unless Owner otherwise consents in writing (which consent may be withheld in Owner’s sole discretion and for any reason), Contractor must complete all Demonstration Tests, as applicable, and remedy all Defects or Deficiencies, which have been identified by such Demonstration Tests, prior to the start of any Performance Tests.

15.3.2 Owner or its Affiliate will cause qualified and experienced personnel to be available to Contractor for use in executing the Performance Tests and any rerun thereof in compliance with this Agreement and Exhibit R. Contractor shall direct and remain responsible for the actions or omissions of the operation and maintenance personnel (including the personnel of Owner or its Affiliate) during the Performance Tests. In addition, Contractor shall provide the services necessary at the Job Site for the installation, start-up and performance of the Commissioning of each LNG Production System and the Facility and the running or rerunning of the Performance Tests in accordance with the requirements of the Performance Tests and the provisions hereof. The Contractor’s Representative shall have full authority to represent Contractor and to acknowledge Defects or Deficiencies in the Facility, direct the proper conduct of remedial actions relating to the performance of the Facility and the execution of the Performance Tests.

15.3.3 Contractor shall provide preliminary Notice to Owner and the Independent Engineer not less than ninety (90) Days prior to the date that Contractor expects the relevant Work and/or Owner Furnished Equipment and Materials to be ready for the Performance Tests. Contractor shall provide an additional Notice to Owner and the Independent Engineer not less than five (5) Business Days prior to the date that Contractor will perform the Performance Tests. The Performance Tests for an LNG Production System or the Facility, as applicable, shall be executed as soon as practicable after LNG Production System Mechanical Completion of such LNG Production System or Facility Mechanical Completion, as applicable, and completion of the Demonstration Tests, as applicable, for such LNG Production System or the Facility; provided that, at Owner’s direction, Contractor shall take into account the interim operations of the Facility by Owner and Owner’s contractual commitments to purchasers of LNG to be produced and loaded at the Facility in scheduling Performance Tests. For the avoidance of doubt, the Parties agree that LNG Production System Mechanical Completion of an LNG Production System or Facility Mechanical Completion, as applicable, will precede the start of the performance of the Demonstration Tests, as applicable, for such LNG Production System or the Facility and that the Demonstration Tests, as applicable, for an LNG Production System or the Facility will precede the start of the Performance Tests for such LNG Production System or the Facility. It is further agreed

 

65


Execution Version

 

that Defects or Deficiencies affecting the safe, proper or reliable operation of an LNG Production System which are discovered prior to achieving LNG Production System Mechanical Completion of an LNG Production System or Facility Mechanical Completion, as applicable, will be remedied before starting the Demonstration Tests, as applicable, for such LNG Production System or the Facility and any such Defects discovered during the performance of the Demonstration Tests, as applicable, for such LNG Production System or the Facility will be remedied prior to the performance of the Performance Tests for such LNG Production System or the Facility. Defects or Deficiencies discovered during any Performance Tests may, in the sole, reasonable judgment of Owner, require remedy and a subsequent Performance Test; provided that, if the immediately prior Performance Test was successfully passed, then any subsequent Performance Test shall not prevent Contractor’s achievement of LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable. Notices by Contractor certifying that each of the aforementioned stages have been completed in full compliance with this Agreement must be accepted by Owner in writing, such acceptance not to be unreasonably withheld or delayed, before Contractor may progress to the subsequent stage.

15.3.4 Contractor shall be responsible to perform all Work necessary, including to correct any Defects and Deficiencies, for the Facility to successfully pass the Performance Tests described in and to the extent required by Exhibit R (including the 72-hour Facility System Reliability Test) (the “Facility Performance Tests”). If: (a) Contractor performs the Facility Performance Tests in accordance with this Agreement and the Facility fails to successfully pass all of the Facility Performance Tests [***] times, or (b) Contractor performs the Facility Performance Tests in accordance with this Agreement and the Facility fails to successfully pass all of the Facility Performance Tests within [***] days after the LPS4 Substantial Completion Date (the earlier to occur of such events, the “Make Good Commencement Date”), then from and after the Make Good Commencement Date Contractor shall be obligated hereunder to perform all Work necessary to successfully pass all of the Facility Performance Tests as soon as reasonably practicable following the Make Good Commencement Date, at its sole cost and expense. Notwithstanding anything contained herein to the contrary, Owner shall have no obligation to pay any Direct Costs, Contractor’s G&A or Contractor’s Margin incurred by Contractor after the Make Good Commencement Date in connection with such Work (excluding, for the avoidance of doubt, any Work that is necessary solely to facilitate the performance by an Owner Contractor of its warranty or make good obligations to Owner in respect of the Owner Furnished Equipment and Materials from and after the Make Good Commencement Date, it being understood that Contractor shall have no obligation to correct defects or deficiencies in the Owner Furnished Equipment and Materials). Without limiting the foregoing, Contractor acknowledges and agrees that its obligation to perform all Work necessary to successfully pass all of the Facility Performance Tests is an absolute, unconditional, “must meet” obligation and is not subject to any limitation on liability or reduction by the payment of liquidated damages or otherwise. Upon successfully passing the Facility Performance Tests, Contractor shall be entitled to payment of its Direct Costs and Contractor’s G&A and Contractor’s Margin applicable thereto in connection with any Reimbursable Work performed after the Facility Substantial Completion Date.

15.3.5 During the Warranty Period, Owner may, or may require Contractor to, conduct a test of any item of Material, component or system that has required modification, repair or replacement under warranty. Such test shall include, where necessary or appropriate, additional

 

66


Execution Version

 

Demonstration Tests or Performance Tests (as described in Exhibit R), in each case, having a scope and duration reasonably necessary to demonstrate the absence of any adverse effect.

15.3.6 If the completed Work, or any section thereof, fails to pass a test required hereunder, Owner may require such failed tests to be repeated under the same terms and conditions.

 

15.4

CORRECTION OF PERFORMANCE DEFECTS OR DEFICIENCIES.

15.4.1 At any time prior to LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable, Contractor shall advise Owner in writing of any (a) Defects or Deficiencies in or (b) defects or deficiencies in the Owner Furnished Equipment and Materials forming part of, such LNG Production System or the Facility, as applicable, that were discovered at any time or that occurred during the Performance Tests for such LNG Production System or the Facility. Contractor shall promptly commence and complete corrective measures to remedy such Defects or Deficiencies; provided, however, that, without prejudice to Contractor’s express obligations related to the Owner Furnished Equipment and Materials as set forth in the definition of “Work” such as integration and installation of Owner Furnished Equipment and Materials, Contractor has no obligation to correct defects or deficiencies in the Owner Furnished Equipment and Materials forming part of such LNG Production System or the Facility. All portions of the Work that contain Defects or Deficiencies not so corrected shall be repaired or removed from the Job Site if necessary. If Contractor fails to initiate correction of Work having such Defects or Deficiencies within seven (7) Days after discovery of such Defects or Deficiencies, Owner may correct such Work, and Owner’s costs associated with uncovering, recovering, correcting and removing Work that contains Defects or Deficiencies, as well as modifying, removing, disassembling, uncovering, rebuilding, re-engineering, replacing or covering or otherwise handling all other Work affected by such Defects or Deficiencies, shall be included in the calculation of Total Costs. If Contractor does not, within ten (10) Days of Notice from Owner, remove or repair Work (or initiate removal thereof) which has Defects or Deficiencies, Owner may, in its discretion, remove, repair, store, sell or dispose of such Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. Contractor shall promptly provide Notice to Owner in writing that such corrective measures have been completed and shall specify in such Notice the date on which the LNG Production System or the Facility will be ready for the Performance Tests to be rerun. Contractor’s obligation to correct Defects or Deficiencies includes uncovering, recovering, correcting and removing Work that contains Defects or Deficiencies, as well as modifying, removing, disassembling, uncovering, rebuilding, re-engineering, replacing or covering or otherwise handling all other Work affected by such Defects or Deficiencies or the correction thereof.

15.4.2 In preparation for the effort to remedy such Defects or Deficiencies discovered after LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable, Owner shall provide personnel and Contractor shall supervise and direct such personnel in the disconnection of the Work from all piping and the cleaning, freeing of liquids, solids, explosives and combustibles, toxic and asphyxiant gases and otherwise making safe for performance of the repair work. Contractor shall promptly provide Notice to Owner in writing that such corrective measures have been completed and shall specify in such Notice the date on which the LNG Production System or the Facility will be ready for the Performance Tests to be rerun. If Contractor fails to initiate correction of Work having such

 

67


Execution Version

 

Defects or Deficiencies within seven (7) Days after discovery of such Defects or Deficiencies, Owner may correct such Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. If Contractor does not, within ten (10) Days of Notice from Owner, repair or remove Work (or initiate removal thereof) which has Defects or Deficiencies, Owner may, in its discretion, remove, repair, store, sell or dispose of such Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

16.

TIME FOR PERFORMANCE AND SCHEDULE.

 

16.1

TIME FOR COMPLETION.

Contractor shall cause (a) each LNG Production System Substantial Completion Date to occur no later than the relevant LNG Production System Substantial Completion Deadline, (b) the Facility Substantial Completion Date to occur no later than the Facility Substantial Completion Deadline, and (c) the Final Completion Date to occur no later than the Final Completion Deadline. If an Applicable Deadline shall be actually, demonstrably and adversely affected by an excusable event hereunder including Owner Caused Delay or Force Majeure Event, and to the extent such delay could not be avoided or mitigated by Contractor, then such Applicable Deadline shall be adjusted pursuant to a Change Order; provided that Contractor shall have provided proper Notice to Owner in accordance with Section 12.1.2 and that the conditions set forth in Section 12.1.3 (if applicable) are satisfied. Contractor will design (to the extent included in the Work) and integrate the Facility, supply all necessary Materials, and schedule its activities (including the scheduling of deliveries as early as practical) taking into account the possible schedule impact of reasonably foreseeable delays and take all reasonably necessary measures to mitigate the effects of any such event enumerated in the preceding sentence and to cause the occurrence of LNG Production System Substantial Completion of each LNG Production System on or before the applicable LNG Production System Substantial Completion Deadline, the occurrence of Facility Substantial Completion on or before the Facility Substantial Completion Deadline and the occurrence of Final Completion on or before the Final Completion Deadline, and to timely perform Corrective Work during the Warranty Period. No delay of an Applicable Deadline shall prejudice any right Owner may have under this Agreement to terminate this Agreement pursuant to the terms of Article 32. Owner’s requirement of correction of any Defect or Deficiency shall not under any circumstances be construed as interference with the Contractor’s performance of the Work. Contractor agrees to exhaust every reasonable repair and replacement alternative in order for the Facility to meet the requirements set forth in this Agreement, including Exhibit A.

 

16.2

FAILURE TO MITIGATE.

If, after an event that has caused Contractor to suspend or delay performance of the Work, Contractor has failed to take such action as Contractor could lawfully and reasonably initiate to remove or relieve either the cause thereof or its direct or indirect effects, Owner may, in its sole discretion and after Notice to Contractor, initiate such reasonable measures as will be designed to remove or relieve such event or its direct or indirect effects and thereafter require Contractor to resume full or partial performance of the Work, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. No action by Owner pursuant to this Section 16.2 shall relieve or excuse Contractor of any of its obligations under this Agreement or constitute the basis for a Change Order.

 

68


Execution Version

 

16.3

RECOVERY AND ACCELERATION OF WORK.

16.3.1 In addition to Contractor’s own recovery plans, if Owner reasonably believes that Contractor will not achieve an Applicable Deadline, then Owner may provide a Notice to Contractor requiring Contractor to propose an additional recovery plan and implement it. Contractor shall be required to present a detailed recovery plan for Owner’s review and concurrence within five (5) Business Days of its receipt of the Notice described in the immediately preceding sentence, which such recovery plan shall include at a minimum the methods of expediting the Work, the additional equipment and tools to be provided and the increased manpower, technology, work shifts and supervision anticipated. Owner may suggest additional resources be added to the recovery plan but such suggestions shall in no way be deemed to limit or otherwise reduce the Contractor’s obligations and liabilities hereunder or Owner’s rights hereunder. If Owner directs Contractor to implement a recovery plan, then Contractor shall implement the recovery plan as provided in this Section 16.3.1. Contractor shall not be entitled to an increase in the Target Price in connection with any recovery plan.

16.3.2 Notwithstanding anything contained herein to the contrary, Owner shall have the right to direct that the Work be accelerated by means of reasonable overtime, additional crews or additional shifts, notwithstanding that the progress of the Work was in accordance with the established Project Schedule. Contractor shall promptly provide to Owner for its approval a plan for such acceleration, including its recommendations for the most effective and economical acceleration, together with such information as Owner shall reasonably require to substantiate the basis of the incremental cost. Prior to the Contractor’s commencement of the accelerated Work, Owner and Contractor shall mutually agree upon the plan for acceleration and the Contractor’s acceleration cost estimate, to be set forth in a Change Order. In addition to Owner’s acceleration rights, Contractor is entitled to request an acceleration plan to be approved by Owner. Should Owner approve such plan, Owner and Contractor shall mutually agree upon the plan for acceleration and the Contractor’s acceleration cost estimate, to be set forth in a Change Order.

 

17.

SUSPENSION OR REJECTION OF THE WORK.

 

17.1

GENERAL.

17.1.1 Owner may at any time or from time to time, and for any reason, suspend performance of the Work or any portion thereof by giving a Suspension Notice to Contractor. Such suspension shall continue for the period (the “Suspension Period”) specified by Owner in the Suspension Notice. At any time after the effective date of the suspension, Owner may require Contractor to resume performance of the Work. In the event a Suspension Notice is issued by Owner under this Section 17.1.1, Contractor shall take such action as is necessary to protect, store and secure the Work, or part thereof, against any deterioration, loss or damage, and if Owner notifies Contractor of the anticipated length of such suspension, Contractor shall use reasonable efforts to delay the performance of any Work to be performed by any Subcontractor.

17.1.2 If Owner reasonably believes that Contractor is (i) in violation of applicable Laws or any Permit and such violation has a material impact on the Facility, (ii) performing Work which has Defects or Deficiencies, is failing to correct Work which has Defects or Deficiencies in a timely manner as practicable, is failing to take the proper precautions at any time when dangerous

 

69


Execution Version

 

conditions exist or (iii) otherwise in breach of this Agreement, then Owner may, by Notice to Contractor, order Contractor to suspend performance of the Work affected by any such failure under this Section 17.1.2 by giving a Suspension Notice to Contractor. Such suspension shall continue for the Suspension Period specified in the Suspension Notice, subject to the following sentence. Upon receipt of such Suspension Notice, Contractor shall (A) suspend performance of the Work to the extent set forth in such Suspension Notice and shall not resume such Work unless and until Contractor and Owner have agreed on those actions to be taken by Contractor to eliminate or cure the cause of such Suspension Notice, and (B) take such action as is necessary to protect, store and secure the Work, or part thereof, against any deterioration, loss or damage, and if Owner notifies Contractor of the anticipated length of such suspension, Contractor shall use reasonable efforts to delay the performance of any Work to be performed by any Subcontractor. Upon resumption of the Work, Contractor shall take all actions as and when required by such agreement with Owner.

 

17.2

COMPENSATION TO CONTRACTOR FOR SUSPENSION.

17.2.1 In the event of a suspension by Owner pursuant to Section 17.1.1, Owner shall issue a Change Order to (a) compensate Contractor for the additional Direct Costs, Contractor’s G&A and the Contractor’s Margin directly attributable to a suspension of items of Work that are documented by Contractor to the satisfaction of Owner and the Independent Engineer; (b) adjust the Target Price to reflect such additional amounts; and (c) adjust the Project Schedule for any delay in the Contractor’s performance of any Critical Path activities, which, in each case, was actually and demonstrably caused by such suspension.

17.2.2 All claims by Contractor for compensation under this Section 17.2 must be made monthly during the Suspension Period and within forty-five (45) Days after the end of the Suspension Period, or Contractor shall be deemed to have waived its rights for compensation with respect thereto. Amounts payable by Owner under this Article 17 shall be paid to Contractor in accordance with Article 6.

 

17.3

REJECTION OF WORK.

Owner shall have the right to inspect Materials or the Work at Contractor’s workshop and at any Subcontractor’s workshop, the Job Site, or at such other places as otherwise may be appropriate, and, prior to LNG Production System Substantial Completion of an LNG Production System or Facility Substantial Completion, as applicable and subject to Contractor’s warranty obligations thereafter, to reject items of Materials or any portion of the Work that has Defects or Deficiencies. Owner shall specify in writing to Contractor the portion of the Materials or portion of Work that it proposes to reject and, prior to actual rejection, Contractor shall have a right to remedy any such Defects or Deficiencies to Owner’s satisfaction. Owner shall have the right to utilize any rejected portion of the Materials or the Work until such time as replacement Material is incorporated into the Facility. These rights shall not be deemed to limit Owner’s rights under Section 15.4.

 

70


Execution Version

 

17.4

CORRECTION OF WORK OR MATERIAL.

Contractor shall promptly correct all Materials or Work rejected by Owner as having Defects or Deficiencies observed before commencement of the Warranty Period of the applicable LNG Production System or any extension thereof, and whether or not fabricated, installed or completed. All portions of the Material or Work that contain Defects or Deficiencies not so corrected shall be repaired or removed from the Job Site if necessary, by Owner in accordance with Section 17.5. Contractor is responsible for removing Material or any portion of the Work that contain Defects or Deficiencies, as well as modifying, removing, disassembling, uncovering, rebuilding, replacing or covering or otherwise handling all other Material or Work affected by such Defects or Deficiencies or the correction thereof. These obligations shall not be deemed to limit Contractor’s obligations under Section 15.4. No action by Owner pursuant to this Section 17.4 shall relieve or excuse Contractor of any of its obligations under this Agreement or constitute the basis for a Change Order.

 

17.5

FAILURE TO CORRECT MATERIAL.

If Contractor fails to initiate correction of Materials or Work having Defects or Deficiencies in accordance with Section 17.4 within five (5) Days of Notice from Owner, Owner may correct such Materials or Work without relieving Contractor of any of its warranty obligations hereunder, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

17.6

OTHER MATERIAL OR WORK DAMAGED.

Owner shall bear the full cost of making good all Materials or any part of the Facility destroyed or damaged by reasonable removal either by Owner as provided in Section 17.5 or by Contractor, but Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

18.

LNG PRODUCTION SYSTEM COMPLETION.

 

18.1

LNG PRODUCTION SYSTEM MECHANICAL COMPLETION.

18.1.1 Upon satisfaction of the conditions set forth in this Section 18.1 for an LNG Production System, Contractor shall give Notice to Owner that LNG Production System Mechanical Completion for such LNG Production System has occurred, which shall only be when all of the following items set forth in this Section 18.1 have occurred:

(a) Contractor has certified to Owner that such LNG Production System has been designed and constructed and is ready for operation or operating in accordance with the requirements set forth in Exhibit A, applicable Laws and Permits and Owner Standards, and have performed all of its obligations under this Agreement then to be performed in relation to such LNG Production System, and the Work is free of all Defects and Deficiencies (other than the Punch List Items);

(b) Owner has received all operations, maintenance and spare parts manuals and instruction books necessary to operate such LNG Production System in a safe, efficient

 

71


Execution Version

 

and effective manner, and Contractor has completed the training program required by Article 14;

(c) Contractor has prepared and submitted for Owner’s approval, and Owner has approved, a safety transition plan for the Facility consistent with the requirements set forth in the HSSE Program;

(d) Contractor has performed all other provisions hereof and delivered all items required hereby to achieve LNG Production System Mechanical Completion of such LNG Production System in a manner reasonably satisfactory to Owner; and

(e) Contractor has delivered to Owner the LNG Production System Mechanical Completion Certificate.

18.1.2 At such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 18.1.1 has been completed with respect to an LNG Production System, Owner shall sign the LNG Production System Mechanical Completion Certificate for such LNG Production System, which shall be dated the date the final item set forth in Section 18.1.1 occurs with respect to such LNG Production System, as determined by Owner.

18.1.3 Notwithstanding anything to the contrary contained herein, Contractor shall retain care, custody, and control of an LNG Production System Handover Package until the corresponding LNG Production System Substantial Completion Date.

 

18.2

LNG PRODUCTION SYSTEM RFSU.

18.2.1 Without limitation of any scheduling requirement contained herein, Contractor shall give Owner at least one hundred eighty (180) Days’ prior Notice to the date on which Contractor expects to achieve LNG Production System RFSU for each LNG Production System. Not less than ninety (90) Days and not more than one hundred twenty (120) Days after each such Notice, Contractor shall give Owner a second Notice specifying the seven (7) Day period during which Contractor expects to achieve LNG Production System RFSU for the applicable LNG Production System. At such time as each LNG Production System achieves LNG Production System RFSU, Contractor shall certify to Owner in the form of an LNG Production System RFSU Certificate that all requirements under this Agreement for LNG Production System RFSU with respect to the applicable LNG Production System have been satisfied. Each LNG Production System RFSU Certificate shall be accompanied by other supporting documentation as may be required under this Agreement to establish, to Owner’s reasonable satisfaction, that the requirements for LNG Production System RFSU have been met, including that Owner has received from Contractor all final Permits relating to such LNG Production System and required to be obtained by Contractor and, if final Permits are not available, all temporary Permits to enable Owner to operate such LNG Production System uninterrupted until such time as such final Permits are obtained. Owner shall by Notice to Contractor confirm whether it accepts or rejects each LNG Production System RFSU Certificate within twenty-four (24) hours following Owner’s receipt thereof. Acceptance of LNG Production System RFSU with respect to an LNG Production System shall be evidenced by Owner’s signature on the applicable LNG Production System RFSU Certificate. The date of LNG Production System RFSU shall be based upon, and the date of

 

72


Execution Version

 

Owner’s acceptance of LNG Production System RFSU shall be deemed to have occurred on, the date listed on the applicable LNG Production System RFSU Certificate; provided that all requirements under this Agreement for LNG Production System RFSU were achieved on such date listed on the applicable LNG Production System RFSU Certificate. If Owner does not agree that LNG Production System RFSU has occurred with respect to a particular LNG Production System, then Owner shall state the basis for its rejection in reasonable detail in such Notice. If the Parties do not mutually agree on when and if LNG Production System RFSU with respect to an LNG Production System has occurred, the Parties shall thereupon promptly and in good faith confer and make all reasonable efforts to resolve such issue. In the event such issue is not resolved within two (2) Business Days of the delivery by Owner of its Notice to Contractor, the Parties shall resolve such Dispute in accordance with Article 36. Owner’s acceptance of LNG Production System RFSU with respect to an LNG Production System shall not relieve Contractor of any of its obligations to perform the Work in accordance with the requirements of this Agreement.

18.2.2 After Owner has accepted the System Turnover Packages, LNG Production System Mechanical Completion has occurred, and the start-up and Pre-Commissioning test reports have been provided to Owner for one (1) or more LNG Production Systems and Contractor has resolved Owner and the Contractor’s lists of Defects or Deficiencies for such LNG Production System(s) (other than the Punch List Items), if any, Contractor shall schedule the cooldown of Tank One or Tank Two, as applicable (each an “LNG Storage Tank Cooldown”). Contractor shall provide Owner with Notice at least one hundred eighty (180) Days’ prior to the date on which Contractor expects LNG Storage Tank Cooldown to occur and shall specify in such Notice the amount of Feed Gas required for LNG Storage Tank Cooldown. Not less than ninety (90) Days and not more than one hundred twenty (120) Days after such Notice, Contractor shall give Owner a second Notice specifying the seven (7) Day period during which Contractor expects LNG Storage Tank Cooldown to occur and confirming the amount of Feed Gas required for LNG Storage Tank Cooldown.

 

18.3

LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION.

18.3.1 Upon compliance with all other conditions set forth in this Section 18.3, Contractor shall give Notice to Owner that LNG Production System Substantial Completion of an LNG Production System has occurred, which shall only be when all of the following items set forth in this Section 18.3 have occurred, unless Owner agrees in writing to waive any such requirements:

(a) all of the conditions for LNG Production System Mechanical Completion of such LNG Production System set forth in Section 18.1 have been met, and Owner has received and accepted the LNG Production System RFSU Certificate for such LNG Production System in accordance with Section 18.2;

(b) Owner has received the relevant System Turnover Packages demonstrating that Contractor has successfully completed all of the Pre-Commissioning and Commissioning of such LNG Production System;

(c) such LNG Production System is ready for normal, continuous and safe operation with the complement of personnel contemplated in Exhibit Q, and Contractor has corrected all Defects and Deficiencies (other than the Punch List Items);

 

73


Execution Version

 

(d) the Performance Tests for such LNG Production System have been satisfactorily completed in accordance with Exhibit R; and

(e) Contractor has delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 18.3.1.

18.3.2 At such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 18.3.1 has been completed with respect to an LNG Production System, Owner shall issue to Contractor a certificate stating the LNG Production System Substantial Completion Date for such LNG Production System, which date shall be the date that Contractor delivered to Owner a certificate certifying the satisfaction of each of the items in Section 18.3.1. If Owner does not either (a) issue such certificate or (b) notify Contractor in writing specifying the reasons why the matters in Section 18.3.1 have not been completed within [***] Business Days from receipt of Contractor’s certificate under Section 18.3.1, then the relevant LNG Production System Substantial Completion Deadline shall be extended by a number of days equal to the period commencing on the Day that immediately follows such [***] Business Day and ends on the Day that Owner responds under clause (a) or (b) above.

 

19.

FACILITY COMPLETION.

 

19.1

FACILITY MECHANICAL COMPLETION.

19.1.1 Upon satisfaction of the conditions set forth in this Section 19.1, Contractor shall give Notice to Owner that Facility Mechanical Completion has occurred, which shall only be when all of the following items set forth in this Section 19.1 have occurred:

(a) all the conditions for LNG Production System Mechanical Completion for all the LNG Production Systems set forth in Section 18.1 have been met, and Owner has received and accepted the LNG Production System RFSU Certificate for all of the LNG Production Systems in accordance with Section 18.2;

(b) Contractor has certified to Owner that the Facility has been designed, integrated and constructed and is ready for operation or operating in accordance with the requirements set forth in Exhibit A, applicable Laws and Permits and Owner Standards, and has performed all of its obligations under this Agreement then to be performed, and the Work is free of all Defects and Deficiencies (other than the Punch List Items);

(c) Owner has received from Contractor all final Permits required to be obtained by Contractor and, if final Permits are not available, all temporary Permits to enable Owner to operate the Facility uninterrupted until such time as such final Permits are obtained;

(d) Contractor has performed all other provisions hereof and delivered all items required hereby to achieve Facility Mechanical Completion in a manner reasonably satisfactory to Owner; and

(e) Contractor has delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 19.1.1.

 

74


Execution Version

 

19.1.2 At such time as Owner and the Independent Engineer have confirmed that each of the foregoing matters have been completed, Owner shall issue to Contractor a certificate stating the Facility Mechanical Completion Date. Facility Mechanical Completion shall be deemed to occur on the date the final item set forth in Section 19.1.1 occurs, as determined by Owner, and not the date such certification is received.

 

19.2

FACILITY SUBSTANTIAL COMPLETION.

19.2.1 Upon compliance with all other conditions set forth in this Section 19.2.1, Contractor shall give Notice to Owner that Facility Substantial Completion has occurred, which shall only be when all of the following items set forth in this Section 19.2.1 have occurred:

(a) all of the conditions for Facility Mechanical Completion set forth in Section 19.1 have been met, and Owner has received and accepted the LNG Production System RFSU Certificate for each LNG Production System in accordance with Section 18.2;

(b) all of the conditions for LNG Production System Substantial Completion set forth in Section 18.3 have been met for all of the LNG Production Systems;

(c) Contractor has made available to Owner at the Job Site all special tools and Spare Parts in accordance with Section 3.9.1 (any reorders to be a Punch List Items in accordance with Section 19.5);

(d) Contractor has successfully completed all of the Demonstration Tests for the Facility, as verified by reports delivered by Contractor to Owner;

(e) Owner has received the System Turnover Packages demonstrating that Contractor has successfully completed all of the Commissioning for the Facility;

(f) the Facility is ready for normal, continuous and safe operation with the complement of personnel contemplated in Exhibit Q, and Contractor has corrected all Defects and Deficiencies (other than the Punch List Items);

(g) Contractor has completed the training program required by Article 14;

(h) Contractor has performed all other provisions hereof and delivered all items required hereby (except any Punch List Items or other obligations of Contractor not intended to be fully performed at Facility Substantial Completion) in a manner satisfactory to Owner;

(i) the Performance Tests for the Facility have been satisfactorily completed in accordance with Exhibit R;

(j) Contractor has paid all amounts to Owner then due and payable hereunder, or Owner has elected to set-off such amounts against any payment that may be owed by Owner to Contractor;

(k) Contractor has provided Owner a complete list of the Punch List Items;

 

75


Execution Version

 

(l) Contractor has prepared, and submitted to Owner’s Representative the operation and maintenance manuals, operating instructions, system checklists and/or procedures in the English language in sufficient detail for Owner to operate, maintain, dismantle, reassemble, adjust and repair the Facility; and

(m) Contractor has delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 19.2.1.

19.2.2 The Facility shall be fully taken over by Owner at such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 19.2.1 has been completed and Owner issues to Contractor a certificate stating the Facility Substantial Completion Date which shall be the date the final item set forth in Section 19.2.1 occurs with respect to the Facility, as determined by Owner, and not the date the certification is received. If Owner does not either (a) issue such certificate or (b) notify Contractor in writing specifying the reasons why the matters in Section 19.2.1 have not been completed within [***] Business Days from receipt of Contractor’s certificate under Section 19.2.1, then the Facility Substantial Completion Deadline shall be extended by a number of days equal to the period commencing on the Day that immediately follows such [***] Business Day and ends on the Day that Owner responds under clause (a) or (b) above.

 

19.3

READY FOR SHIP LOADING.

Without limiting the foregoing or any other scheduling requirements contained herein, Contractor shall provide Owner (a) at least one hundred eighty (180) Days’ prior Notice of the day on which Contractor expects to be ready for Owner or its Affiliate to perform the Loading Rate Test, and (b) a second Notice specifying the date on which Contractor expects to be ready for the Loading Rate Test, which second Notice shall be given no later than sixty (60) Days prior to such date. Owner shall cause an LNG Tanker to be available, after the date in such second Notice; provided that Owner is not required to schedule such LNG Tanker until (a) there is sufficient LNG in storage in the LNG Storage Tanks to perform the Loading Rate Test, and (b) Owner has the ability and an economic reason to export such LNG. Owner shall give Contractor fourteen (14) Days prior written notice of a five (5)-Day period in which the LNG Tanker will be available for the Loading Rate Test. Contractor shall assist Owner in identifying prospective LNG Tanker operators to conduct assurance and vetting of the marine terminal, and shall provide reasonable access to the Job Site to such operators and to other LNG Tanker operators who are anticipated to use the Facility to conduct such assurance and vetting activities.

 

19.4

FINAL COMPLETION.

19.4.1 Final Completion of the Facility shall occur no later than the Final Completion Deadline. In order to achieve Final Completion, Contractor must have:

(a) met all the conditions for Facility Substantial Completion set forth in Section 19.2;

(b) completed a Facility final clean-up including removal from the Job Site of all construction debris, bulk construction materials, storage trailers, temporary facilities,

 

76


Execution Version

 

scaffolding, temporary protection and other impediments that would interfere with the normal operation and maintenance of the Facility, and Contractor has delivered the Facility in a clean condition satisfactory to Owner in accordance with the procedures set forth in Exhibit A;

(c) completed all Punch List Items, which Punch List Items shall be promptly completed upon receipt of such Material(s) or other event(s) and corrected all Defects and Deficiencies identified by Owner during the Performance Tests which Owner has decided to not require completion and re-running of the Performance Tests, and Owner must have accepted such corrections in writing;

(d) delivered to Owner all electronic files in the format designated by Owner, all Drawings and Specifications (including red-lined “as-built” drawings of such LNG Production System), test data and other technical information relating to such LNG Production System and required hereunder for Owner to operate and maintain such LNG Production System;

(e) delivered to Owner all as-built operations, maintenance and spare parts manuals and instruction books that are necessary to operate the Facility in a safe, efficient and effective manner, and Contractor has completed the training program required by Article 14;

(f) delivered to Owner all electronic files in the format designated by Owner, all Drawings and Specifications (except final “as-built” drawings of the Facility, but including red-lined “as-built” drawings of the Facility), test data and other technical information required hereunder for Owner to operate and maintain the Facility;

(g) delivered to Owner final “as built-” drawings for the Facility as required by Section 3.8.43 and meeting the requirements of Exhibit J;

(h) removed all the Contractor’s and Subcontractors’ personnel, supplies, equipment, waste materials, rubbish and temporary facilities from the Job Site (unless otherwise requested by Owner);

(i) delivered evidence satisfactory to Owner, including a Payment Status Affidavit from Contractor and all Major Subcontractors in the form of Exhibit F-15 and Exhibit F-16, respectively, and a final and unconditional release and waiver of liens from Contractor and all Major Subcontractors in the form of Exhibit F-3 and Exhibit F-4, respectively, that all claims, liens, security interests or encumbrances in the nature of mechanics’, labor or materialmen’s liens (if applicable) arising out of or in connection with the Job Site, Facility (or any portion thereof), any Materials, any land or improvements pertinent thereto or the performance by Contractor or any Major Subcontractor of the Work have been satisfied or discharged;

(j) performed all other provisions hereof and delivered all items required hereby (except any warranty or other obligation of Contractor not intended to be fully performed at Final Completion) in a manner satisfactory to Owner;

 

77


Execution Version

 

(k) paid all undisputed amounts to Owner then due and payable hereunder; and

(l) delivered to Owner a certificate certifying the satisfaction of each of the foregoing items in this Section 19.4.1.

19.4.2 At such time as Owner and the Independent Engineer have confirmed that each of the matters set forth in Section 19.4.1 has been completed, Owner shall issue a Final Completion certificate. Notwithstanding the foregoing, nothing contained in this Section 19.4 shall relieve Contractor from performing any obligations remaining under this Agreement after Final Completion, including any of its warranty obligations hereunder.

 

19.5

PUNCH LIST ITEMS.

Notwithstanding anything to the contrary contained herein, at Owner’s sole discretion, Owner may approve the completion of Punch List Items after Final Completion; provided, however, that if any such Punch List Items remain outstanding at Final Completion, Contractor shall cause the Contractor Guarantee to remain in full force and effect until Contractor’s completion of all of such Punch List Items to Owner’s satisfaction. If Contractor does not promptly complete any remaining Punch List Item, Owner shall have the right to complete such item and Owner’s costs associated with such activities shall be included in the calculation of Total Costs. Notwithstanding anything to the contrary contained herein, however, if the completion of any Punch List Items requires that an LNG Production System or the Facility be shut down or its output curtailed, Owner shall have the option of completing such Punch List Items itself, and Owner’s costs associated with completion of any such Punch List Items (excluding costs associated with shut down or of output curtailment) shall be included in the calculation of Total Costs.

 

20.

WARRANTY FOR DEFECTS.

 

20.1

IN GENERAL.

20.1.1 As further described herein, Contractor shall repair or replace all Defects and Deficiencies prior to the commencement of the Warranty Period. Except as provided in Section 15.3.4, Contractor shall be paid the Direct Costs incurred in fulfilling its obligations under this Section 20.1.1 prior to the commencement of the Warranty Period. Upon commencement of the Warranty Period, Contractor shall be required to perform all Corrective Work (defined below), and all costs incurred by Contractor to perform such Corrective Work shall be considered Non-Reimbursable Costs as further provided in Exhibit B-1.

20.1.2 During the Warranty Period, Contractor shall, as soon as practicable, complete any Work that is outstanding at Final Completion and shall be responsible for performing Corrective Work which may appear or occur during the Warranty Period or any extension thereof.

20.1.3 During the Warranty Period, Contractor shall make good the Defects or Deficiencies in the Work promptly and on an expedited basis whether by repair, replacement or otherwise (the “Corrective Work”). In the event Contractor utilizes spare parts owned by Owner in the course of performing the Corrective Work or Work as provided in Section 20.1.4, Contractor

 

78


Execution Version

 

shall supply Owner with new spare parts equivalent in quality and quantity to all such spare parts used by Contractor as soon as possible following the utilization of such spare parts.

20.1.4 If Contractor is obligated to repair, replace or renew a Serial Defect, Contractor shall undertake a technical analysis of the problem and correct the “root cause” unless Contractor can demonstrate to Owner’s satisfaction that there is not a risk of the reoccurrence of such problem. Contractor’s obligations under this Article 20 shall not be impaired or otherwise adversely affected by any actual or possible legal obligation or duty of any Subcontractor, in each case, to Contractor or Owner concerning any Defect or Deficiency. No such correction or cure, as the case may be, shall be considered complete until Owner shall have reviewed and approved such remedial work in accordance with this Agreement.

 

20.2

SPECIFIC WARRANTIES.

In particular, Contractor warrants to Owner that:

20.2.1 Contractor shall perform the Work in full compliance with the terms and conditions set forth herein;

20.2.2 the Materials and the Work shall be designed, manufactured, engineered, constructed, completed, pre-commissioned, commissioned, tested and delivered in accordance with this Agreement;

20.2.3 the Materials and the Work shall be designed, manufactured, engineered, constructed, completed, tested and delivered, in a workmanlike manner and in accordance with this Agreement, Owner Standards, all Permits and approvals of Government Authorities, Applicable Codes and Standards and all applicable Laws;

20.2.4 the Work, including all Materials and each component thereof (a) shall conform to the specifications and descriptions set forth herein, (b) shall be new, complete, and of suitable grade for the intended function and use in accordance with this Agreement, (c) shall be free from defects (including latent defects) in design, material and workmanship, and (d) shall meet the requirements set forth in Exhibit A;

20.2.5 the Materials, or any component of Materials, shall be composed and made of only proven technology, of a type in commercial operation at the Effective Date; provided that Owner’s agreement for Contractor to use any Materials not in compliance with this Section 20.2.5 shall not relieve Contractor of any of its other obligations under this Agreement;

20.2.6 if, prior to the expiration of the Warranty Period, two (2) or more of the same components of the Work experience a Defect of an identical or nearly identical nature that causes or could reasonably be expected to cause an outage or derating of the Facility (herein, a “Serial Defect”), then Contractor shall examine the cause of the Serial Defect and (i) undertake technical analysis of the underlying problem in order to determine (A) the root cause of such Serial Defect, and (B) the repairs or replacements that may be required to avoid future occurrences of such Serial Defect, (ii) prepare and provide to Owner a written report setting forth the results of such analysis, (iii) promptly redesign if necessary and repair or replace any Materials, as necessary, and (iv) extend the Warranty Period for that portion of the Work that Contractor redesigned, repaired

 

79


Execution Version

 

or replaced for an additional period of [***] months. Such warranty extension for Serial Defects is in lieu of and not in addition to the extension of the Warranty Period contemplated in Section 20.4.2.

20.2.7 Contractor shall, at all times during the Warranty Period, maintain sufficient personnel at Contractor’s offices to respond promptly to Owner’s request for diagnostic or warranty work. At any time during the Warranty Period, Contractor shall promptly and on an expedited basis perform such tests, inspections or other diagnostic services as may be reasonably requested by Owner. In the event that such diagnostic services reveal any Work not conforming to the Contractor’s Warranties, any and all such Work shall be corrected immediately as Corrective Work (the warranties set forth in Sections 20.2.1 to 20.2.7 inclusively are referred to collectively as the “Warranties”). The Warranties shall not include work performed under the Owner Contracts; and

20.2.8 Contractor shall, in the course of correcting any Defects or Deficiencies, do so (a) in good faith coordination with Owner’s schedule of operations so as to minimize any adverse effect on the operations of the Facility, and (b) in accordance with the Warranty procedures set forth in this Article 20.

 

20.3

NOTICE OF DEFECTS OR DEFICIENCIES.

If any Defects, Deficiencies or resulting damage to the Work appear or arise from notifications by manufacturers of Material, Owner shall promptly notify Contractor of such Defects, Deficiency or damage, and Contractor shall perform the necessary repairs or replacements in accordance with its Warranty obligations. Owner shall be entitled to determine the existence of any Defects, Deficiencies or damage.

 

20.4

EXTENSION OF WARRANTY PERIOD.

20.4.1 The provisions of this Article 20 shall apply to all replacements or repairs carried out by Contractor as if the replacements and repairs had been taken over on the date they were completed. All Corrective Work shall be performed subject to the same terms and conditions under this Agreement as the original Work is required to be performed. Any change to parts or Materials that would alter the requirements of this Agreement may be made only with prior written approval of Owner.

20.4.2 The Warranty Period for the Work or portion thereof that Contractor has replaced or repaired shall be extended by a period of [***] months from the date the replacement or repair is completed (and for successive periods of [***] months in the event of any Defect or Deficiency associated with any such replacement or repair), but in no event shall the Warranty Period extend beyond [***] months following Facility Substantial Completion.

 

20.5

FAILURE TO REMEDY DEFECTS.

If Contractor fails to commence any Corrective Work within a reasonable period of time not to exceed five (5) Days after receipt of Owner’s written notice to Contractor identifying and describing with reasonable specificity that portion of Work that has a Defect or Deficiency, or does not complete such Corrective Work on an expedited basis, Owner may, in its sole discretion and

 

80


Execution Version

 

in addition to any other remedies that it has under this Agreement, proceed to do the Work and, subject to Section 16.2, notify Contractor of its intention to do so, and Owner’s costs associated with such activities shall be included in the calculation of Total Costs.

 

20.6

REMOVAL AND OWNERSHIP OF DEFECTIVE WORK.

If the Defects, Deficiencies or resultant damage is such that it cannot be remedied expeditiously on the Job Site, Contractor may, with the prior written consent of Owner’s Representative or Owner, remove from the Job Site for the purposes of repair or replacement of any part of the Work which is defective, deficient or damaged.

 

20.7

FURTHER TESTS.

If the repair or replacement of any equipment or components of Work is such that it may affect the operation of the Work or any part thereof, then Owner may require that tests of such equipment or components or any affected part of the Work thereof be conducted by Contractor and repeated to the extent reasonably necessary. Such requirement shall be made by Notice within thirty (30) Days after the Defect or Deficiency is remedied. Such tests shall verify that the equipment or component or any affected part of the Work thereof, as the case may be, is at the same level of performance as existed prior to the need for repair or replacement.

 

20.8

RIGHT OF ACCESS.

Until the expiration of the Warranty Period, but only to the extent required to perform its obligations hereunder, Contractor shall have the right of reasonable access to all parts of the Work and to records of the working and performance of the Work, except as may be inconsistent with any reasonable security or safety restrictions of the Owner. Such right of access shall be undertaken so as to minimize interference with the operation of the Facility. Access shall be granted to any duly authorized representative of Contractor whose name has been communicated in writing to Owner and who agrees to be bound by Owner Protocols and the confidentiality provisions of this Agreement in connection with such access. The Parties shall schedule corrections, repairs or replacements as necessary so as to minimize disruptions to the operation of the Facility.

 

20.9

SUBCONTRACTOR WARRANTIES.

20.9.1 Contractor shall, for the protection of Contractor and Owner, use reasonable efforts to obtain from the Subcontractors such guarantees and warranties with respect to Work performed that are equal to or exceed those set forth in this Article 20 as applicable to their respective scopes of work and shall be made available and in the name of Owner and assignable to the Lenders to the full extent of the terms thereof. Subject to Section 23.1.4, Contractor shall enforce all Subcontractor warranties in accordance with their terms so as to minimize the amount of Work Contractor may be required to perform to correct any Defect or Deficiency in the Subcontractors’ work. Owner shall be an express third-party beneficiary of all such guarantees and warranties. To the extent available, Owner shall have the right to require Contractor to secure additional warranty or extended guarantee protection pursuant to a Change Order. Upon the earlier of the date of Final Completion or termination of this Agreement, Contractor shall deliver to Owner copies of all relevant contracts providing for such guarantees and warranties.

 

81


Execution Version

 

20.9.2 Upon the earlier of Final Completion or termination of this Agreement, Contractor shall assign to Owner all warranties received by it from Subcontractors that are not otherwise issued in Owner’s name. Such assignment of warranties to Owner must also allow Owner to further assign such warranties. However, Owner shall not make any warranty claim against Contractor with respect to any portion of the Work supplied in whole or in part by any Subcontractor if and to the extent Contractor has previously assigned all warranties received by it from such Subcontractor to Owner.

 

20.10

NO IMPLIED WARRANTIES.

EXCEPT FOR THE EXPRESS WARRANTIES SET FORTH IN THIS ARTICLE 20 (INCLUDING THE “WARRANTIES”), CONTRACTOR DOES NOT MAKE ANY OTHER WARRANTIES, WHETHER STATUTORY, EXPRESS OR IMPLIED (INCLUDING ANY IMPLIED WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE AND ALL WARRANTIES ARISING FROM COURSE OF DEALING OR USAGE OF TRADE). OWNER’S EXCLUSIVE REMEDIES AND CONTRACTOR’S ONLY OBLIGATIONS ARISING OUT OF OR IN CONNECTION WITH DEFECTS OR DEFICIENCIES IN THE WORK (PATENT, LATENT OR OTHERWISE), WHETHER BASED IN CONTRACT, IN TORT (INCLUDING NEGLIGENCE AND STRICT LIABILITY), OR OTHERWISE, ARE SET FORTH IN THIS ARTICLE 20. ALL SUCH OTHER WARRANTIES, CONDITIONS AND REPRESENTATIONS ARE HEREBY DISCLAIMED. THE FOREGOING IS NOT INTENDED TO DISCLAIM ANY OTHER OBLIGATIONS OF CONTRACTOR WHICH ARE UNRELATED TO DEFECTS OR DEFICIENCIES IN THE WORK AS EXPRESSLY SET FORTH HEREIN.

 

20.11

REPAIRS AND TESTING BY OWNER.

20.11.1 During the Warranty Period, without prior notice to Contractor Owner, by itself or through its Affiliate, shall be permitted to (a) make repairs or replacements on the Materials or the Facility, and (b) adjust or test the Materials or the Facility as outlined in the operations and maintenance manuals provided by Contractor or any Subcontractor.

20.11.2 In the event of an emergency and if, in the judgment of Owner, the delay that would result from giving prior notice to Contractor could cause serious loss or damage which could be prevented by immediate action, any action (including correction of Defects) may be taken by Owner or a third party chosen by Owner, without giving prior notice to Contractor. In the event such action is taken by Owner, Contractor shall be promptly notified after Corrective Work is implemented, and shall assist whenever and wherever possible in making the necessary corrections. All such warranties obtained shall be in addition to, and shall not alter, the warranties of Contractor. Upon Owner’s request, Contractor shall use all reasonable efforts to force Subcontractors to honor warranties including filing suit to enforce same.

 

20.12

SURVIVAL OF WARRANTIES.

Prior to the end of the Warranty Period, the provisions of this Article 20 shall survive the expiration or earlier termination of this Agreement. The Warranties made herein shall be for the benefit of Owner and its successors and permitted assigns and the respective successors and

 

82


Execution Version

 

permitted assigns of any of them, and are fully transferable and assignable. Owner may assign its rights to the Warranties during the Warranty Period to any Affiliate, Lender, or any Person acquiring a substantial ownership interest in the Facility without the consent of Contractor.

 

21.

LIABILITY.

 

21.1

TOTAL LIABILITY CAP.

Notwithstanding anything to the contrary contained herein, Contractor’s cumulative aggregate liability hereunder, whether in contract, warranty (including in respect of Corrective Work), tort, (including negligence whether sole or concurrent), strict liability, products liability, professional liability, indemnity, contribution, statute, at law, in equity, or any other cause of action, shall not exceed an amount equal to [***] provided that, notwithstanding the foregoing, the limitation of liability set forth in this Section 21.1 shall not: (a) apply in the event of Abandonment of the Project by Contractor; (b) apply to Contractor’s indemnification obligations under this Agreement with respect to: (i) any claims brought by Third Parties (for purposes of this Section 21.1 “Third Parties” shall include Owner’s and its Affiliate’s employees) for bodily injury, death or property damage as described in Section 30.1.2(b); or (ii) costs and expenses incurred by Contractor to fulfill those express indemnity obligations set forth in Sections 5.1.2, 6.4.2, 30.1.1, 30.1.2, 30.1.3 and 40.4.2; (c) apply to Contractor’s obligation to deliver to Owner full legal title to and ownership of all or any portion of the Work as required under this Agreement; (d) include the payment of insurance proceeds under any Project-specific insurance policy obtained by Contractor; (e) include any amount in respect of any Non-Reimbursable Cost, provided that Schedule Delay Liquidated Damages shall count towards and be subject to the cap; (f) apply in the event of the gross negligence or willful misconduct of Senior Supervisory Personnel or the willful misconduct of Contractor, its agents or Affiliates (including the Contractor Guarantor), workers, Senior Supervisory Personnel, Subcontractors and suppliers or the employees of each; (g) apply to limit Contractor’s costs incurred to achieve the “make good” obligations under Section 15.3.4 or (h) take into account or otherwise be affected by any reduction in Contractor’s entitlement to the payment of or forfeiture of the Margin Percentage.

 

21.2

NO CONSEQUENTIAL DAMAGES.

Notwithstanding anything to the contrary contained herein, except with respect to (a) any claims for bodily injury, death or physical damage to property of Third Parties for which Contractor owes an indemnity obligation as described in Section 30.1.2(b), (b) any damages resulting from the gross negligence or willful misconduct of Senior Supervisory Personnel or the fraud and willful misconduct of Contractor, its agents or Affiliates (including the Contractor Guarantor), workers, Senior Supervisory Personnel, Subcontractors and suppliers or the employees of each, (c) any liquidated damages which may be payable as set forth in Article 22, and (d) any damages resulting from Contractor’s breach of Article 27, Contractor, its agents and Affiliates (including the Contractor Guarantor), workers, Subcontractors and suppliers and the employees of each shall not be liable for, and Owner hereby waives any incidental, indirect, punitive or consequential damages, loss of or default under business contracts, lost revenues or for loss of profit, product, revenue, contract or use arising out of or in connection with the performance of the Work or this Agreement whether or not any such liability is claimed in contract, statute,

 

83


Execution Version

 

equity, tort or otherwise and shall apply irrespective of negligence. In addition, except with respect to (a) Third Party claims for which Owner has agreed to indemnify Contractor in accordance with Section 30.2, and (b) Owner’s breach of its confidentiality obligations under Article 27, Owner shall have no liability for, and Contractor hereby waives, releases, defends, indemnifies and holds harmless any incidental, indirect, punitive or consequential damages (which includes loss of or default under business contracts, lost revenues or lost profits but excluding those amounts payable by Owner to Contractor in the event of a termination for default pursuant to Section 31.5 or for convenience pursuant to Article 32) arising out of or in connection with this Agreement.

 

22.

PERFORMANCE TESTS; LIQUIDATED DAMAGES.

 

22.1

PERFORMANCE TESTS.

The Performance Tests are described in Exhibit R.

 

22.2

SCHEDULE DELAY LIQUIDATED DAMAGES FOR FAILURE TO ACHIEVE LNG PRODUCTION SYSTEM SUBSTANTIAL COMPLETION OR FACILITY SUBSTANTIAL COMPLETION BY AN APPLICABLE DEADLINE.

22.2.1 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the LPS1 Substantial Completion Date has not occurred on or before the date that is [***] days after the LPS1 Substantial Completion Deadline, Contractor shall:

(a) pay LPS1 Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the LPS1 Substantial Completion Date, and (ii) the Day on which Contractor has paid LPS1 Schedule Delay Liquidated Damages in an amount equal to the LPS1 Schedule Delay Liquidated Damages Cap, in the following amounts:

(1) for the period commencing on the date that is [***] days after the LPS1 Substantial Completion Deadline and ending on the date that is [***] days after the LPS1 Substantial Completion Deadline, [***] per day;

(2) for the period commencing on the date that is [***] days after the LPS1 Substantial Completion Deadline and ending on the date that is [***] days after the LPS1 Substantial Completion Deadline, [***] per day;

(3) for the period commencing on the date that is [***] days after the LPS1 Substantial Completion Deadline and ending on the date that is [***] days after the LPS1 Substantial Completion Deadline, [***] per day; and

(4) for the period commencing on the date that is [***] days after the LPS1 Substantial Completion Deadline and ending on the date that is [***] days after the LPS1 Substantial Completion Deadline, [***] per day.

 

84


Execution Version

 

22.2.2 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the LPS2 Substantial Completion Date has not occurred on or before the date that is [***] days after the LPS2 Substantial Completion Deadline, Contractor shall pay LPS2 Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the LPS2 Substantial Completion Date and (ii) the Day on which Contractor has paid LPS2 Schedule Delay Liquidated Damages in an amount equal to the LPS2 Schedule Delay Liquidated Damages Cap, in the following amounts:

(a) for the period commencing on the date that is [***] days after the LPS2 Substantial Completion Deadline and ending on the date that is [***] days after the LPS2 Substantial Completion Deadline, [***] per day;

(b) for the period commencing on the date that is [***] days after the LPS2 Substantial Completion Deadline and ending on the date that is [***] days after the LPS2 Substantial Completion Deadline, [***] per day;

(c) for the period commencing on the date that is [***] days after the LPS2 Substantial Completion Deadline and ending on the date that is [***] days after the LPS2 Substantial Completion Deadline, [***] per day; and

(d)) for the period commencing on the date that is [***] days after the LPS2 Substantial Completion Deadline and ending on the date that is [***] days after the LPS2 Substantial Completion Deadline, [***] per day.

22.2.3 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the LPS3 Substantial Completion Date has not occurred on or before the date that is [***] days after the LPS3 Substantial Completion Deadline, Contractor shall pay LPS3 Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the LPS3 Substantial Completion Date and (ii) the Day on which Contractor has paid such LPS3 Schedule Delay Liquidated Damages in an amount equal to the LPS3 Schedule Delay Liquidated Damages Cap, in the following amounts:

(a) for the period commencing on the date that is [***] days after the LPS3 Substantial Completion Deadline and ending on the date that is [***] days after the LPS3 Substantial Completion Deadline, [***] per day;

(b) for the period commencing on the date that is [***] days after the LPS3 Substantial Completion Deadline and ending on the date that is [***] days after the LPS3 Substantial Completion Deadline, [***] per day;

 

85


Execution Version

 

(c) for the period commencing on the date that is [***] days after the LPS3 Substantial Completion Deadline and ending on the date that is [***] days after the LPS3 Substantial Completion Deadline, [***] per day; and

(d) for the period commencing on the date that is [***] days after the LPS3 Substantial Completion Deadline and ending on the date that is [***] days after the LPS3 Substantial Completion Deadline, [***] per day.

22.2.4 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the LPS4 Substantial Completion Date has not occurred on or before the date that is [***] days after the LPS4 Substantial Completion Deadline, Contractor shall pay LPS4 Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the LPS4 Substantial Completion Date and (ii) the Day on which Contractor has paid such LPS4 Schedule Delay Liquidated Damages in an amount equal to the LPS4 Schedule Delay Liquidated Damages Cap, in the following amounts:

(a) for the period commencing on the date that is [***] days after the LPS4 Substantial Completion Deadline and ending on the date that is [***] days after the LPS4 Substantial Completion Deadline, [***] per day;

(b) for the period commencing on the date that is [***] days after the LPS4 Substantial Completion Deadline and ending on the date that is [***] days after the LPS4 Substantial Completion Deadline, [***] per day;

(c) for the period commencing on the date that is [***] days after the LPS4 Substantial Completion Deadline and ending on the date that is [***] days after the LPS 4 Substantial Completion Deadline, [***] per day; and

(d) for the period commencing on the date that is [***] after the LPS4 Substantial Completion Deadline and ending on the date that is [***] days after the LPS4 Substantial Completion Deadline, [***] per day.

22.2.5 In addition to the other liquidated damages required to be paid by Contractor pursuant to this Agreement, if the Facility Substantial Completion Date has not occurred on or before the date that is [***] days after the Facility Substantial Completion Deadline, Contractor shall pay Facility Schedule Delay Liquidated Damages to Owner for each and every Day which elapses after such date until the earlier of (i) the Facility Substantial Completion Date and (ii) the Day on which Contractor has paid Facility Schedule Delay Liquidated Damages in an amount equal to the Facility Schedule Delay Liquidated Damages Cap, in the following amounts:

(a) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] days after the Facility Substantial Completion Deadline, [***] per day;

 

86


Execution Version

 

(b) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] days after the Facility Substantial Completion Deadline, [***] per day;

(c) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] days after the Facility Substantial Completion Deadline, [***] per day; and

(d) for the period commencing on the date that is [***] days after the Facility Substantial Completion Deadline and ending on the date that is [***] after the Facility Substantial Completion Deadline, [***] per day.

22.2.6 Except as set forth in Section 31.2, Contractor’s payment of Schedule Delay Liquidated Damages as set forth in Sections 22.2.1 through 22.2.5, and the other remedies set forth in Section 22.2.1(b) and (c), shall be the sole and exclusive remedy of Owner for Contractor’s failure to achieve the LPS1 Substantial Completion Date on or before the LPS1 Substantial Completion Deadline, the LPS2 Substantial Completion Date on or before the LPS2 Substantial Completion Deadline, the LPS3 Substantial Completion Date on or before the LPS3 Substantial Completion Deadline, the LPS4 Substantial Completion Date on or before the LPS4 Substantial Completion Deadline or the Facility Substantial Completion Date on or before the Facility Substantial Completion Deadline.

22.2.7 In the event that the Work fails to achieve any of the requirements provided in this Agreement required to achieve LNG Production System Substantial Completion or Facility Substantial Completion, as evidenced by the Performance Test results, by the LNG Production System Substantial Completion Deadline for an LNG Production System or the Facility Substantial Completion Deadline, as applicable, then LNG Production System Substantial Completion of such LNG Production System or Facility Substantial Completion, as applicable, shall not occur.

 

22.3

LIQUIDATED DAMAGES CAP.

22.3.1 The total amount of Contractor’s obligations to pay Schedule Delay Liquidated Damages pursuant to Section 22.2 shall not exceed the following amounts:

(a) LPS1 Schedule Delay Liquidated Damages shall not exceed [***] (the “LPS1 Schedule Delay Liquidated Damages Cap”);

(b) LPS2 Schedule Delay Liquidated Damages shall not exceed [***] (the “LPS2 Schedule Delay Liquidated Damages Cap”);

 

87


Execution Version

 

(c) LPS3 Schedule Delay Liquidated Damages shall not exceed [***] (the “LPS3 Schedule Delay Liquidated Damages Cap”);

(d) LPS4 Schedule Delay Liquidated Damages shall not exceed [***] (the “LPS4 Schedule Delay Liquidated Damages Cap”); and

(e) Facility Schedule Delay Liquidated Damages shall not exceed [***] (the “Facility Schedule Delay Liquidated Damages Cap”).

22.3.2 If at any time Contractor is as a result of the operation of Section 22.3.1 no longer liable hereunder to pay Schedule Delay Liquidated Damages, then Owner may terminate this Agreement in accordance with Sections 31.1.16 and 31.4 or continue to permit Contractor to progress the Work in accordance with the requirements of this Agreement.

 

22.4

PAYMENT.

22.4.1 Schedule Delay Liquidated Damages shall accrue daily hereunder and shall be payable by Contractor monthly, no later than the fifth (5th) Business Day of the immediately following month.

22.4.2 All liquidated damage amounts required to be paid by Contractor under this Article 22 shall cease accruing upon a termination of this Agreement.

 

22.5

LIQUIDATED DAMAGES REASONABLE.

The Parties acknowledge and agree that actual damages for Contractor’s failure to successfully pass the Performance Tests and achieve the relevant milestones by the Applicable Deadlines are difficult to determine and that the liquidated damages set forth herein are reasonable and appropriate measures of the damages for such failure, are apportioned in a fair and appropriate manner including with respect to any lump-sum liquidated damages that may be payable in respect of any single day of delay, and do not represent a penalty. If Contractor, the Contractor Guarantor or anyone on its behalf successfully challenges the applicable rate of any liquidated damages, Contractor specifically agrees to pay Owner all actual damages incurred by Owner in connection with such breach, including any and all consequential damages (such as loss of profits and revenues, business interruption, loss of opportunity and use) and all costs incurred by Owner in proving the same, without regard to any limitations whatsoever set forth herein. Notwithstanding any provision to the contrary and except as provided in Section 31.2.1 (in respect of a Contractor event of default described in Section 31.1.9), Contractor’s payment of liquidated damages shall constitute Owner’s exclusive remedy for Contractor’s failure to achieve the relevant milestones by the Applicable Deadlines.

 

22.6

EFFECT ON OTHER PROVISIONS.

The provisions of this Article 22 shall affect neither Contractor’s obligations to complete any other requirement herein which is unrelated to schedule nor Owner’s right to withhold amounts retained under Section 6.8 hereof.

 

88


Execution Version

 

23.

SUBCONTRACTORS.

23.1.1 Attached as Exhibit H and Exhibit O is a list of names of potential Major Subcontractors. Contractor may submit to Owner the names and qualifications and recommendations of additional Major Subcontractors that it desires to include in Exhibit H or Exhibit O. Any additions or changes to Exhibit H or Exhibit O shall be decided solely by Owner within a reasonable time following the submission of all necessary supporting documentation by Contractor. At the request of Owner, the Lenders or Owner’s title insurance providers, Contractor shall provide an affidavit of all Major Subcontractors, in a form acceptable to Owner, the Lenders or Owner’s title insurance providers, as applicable. All Major Subcontractors will be selected from Exhibit H or Exhibit O as supplemented from time to time in accordance with this Section 23.1.1. Contractor shall not enter into Major Subcontracts with any Person not listed in Exhibit H or Exhibit O without the prior written approval of Owner. Contractor shall issue all Subcontracts in accordance with the terms of this Agreement. Approval by Owner of any Subcontractor or its receipt or review of any Subcontract shall not (a) relieve Contractor of any of its obligations under this Agreement or (b) constitute any acceptance of the Work undertaken by such Person. No Subcontract shall bind or purport to bind Owner.

23.1.2 Contractor shall include in each Major Subcontract a provision requiring each such Major Subcontractor to comply with and perform for the benefit of Owner all requirements and obligations of Contractor to Owner under this Agreement, to the extent such requirements and obligations are applicable to the performance of the work under the respective Major Subcontract. At a minimum, all Subcontracts shall require the Subcontractors to comply with applicable Laws, Applicable Codes and Standards and Permits, shall provide that Owner has the right of inspection as provided hereunder and require such Subcontractors to (a) be subject to the labor obligations hereunder as well as the safety and security provisions of this Agreement, (b) provide guarantees and warranties with respect to its portion of the Work commensurate with such Major Subcontractor’s work, (c) provide certificates of insurance as set forth herein, (d) grant a license to Owner pursuant to Section 29.2.3, (e) include a termination for convenience provision with terms consistent with the terms set forth herein, and (f) be subject to the confidentiality provisions consistent with the terms set forth herein. Contractor shall use its reasonable efforts to minimize or eliminate cancellation charges or fees in each Subcontract. Additionally, Contractor shall include in each Major Subcontract relating to any Materials or other component of the Facility a requirement that, until the end of the Warranty Period, the Subcontractor shall (i) notify Contractor and Owner in the event Subcontractor intends to discontinue supplying any functional spare parts and (ii) permit Owner to order any quantity of any such parts at the prices prevailing prior to such discontinuance of supply. All Subcontracts must specify that the contractual relationship with the Subcontractor is exclusive to Contractor and that the Subcontractor waives any and all rights to demand any payment directly from Owner.

23.1.3 In addition to the requirements set forth above, Contractor shall include in each Subcontract the following language to make Owner an express third party beneficiary of such Subcontract:

“The parties hereto agree and acknowledge that the services/work/equipment to be provided hereunder by [Subcontractor] will be incorporated into the LNG facility and related facilities being developed by [Owner]. As such, the parties expressly

 

89


Execution Version

 

agree that Owner is a third party beneficiary of this [Agreement] entitled, in its own name or in the name of [Contractor], to enforce this [Agreement] against [Subcontractor].”

23.1.4 Contractor shall notify Owner of and coordinate with Owner in connection with the administration of any claim (actual or threatened in writing) arising under any Subcontract, and shall request Owner’s approval (such approval not to be unreasonably withheld or delayed) (a) of any external attorney and claims consultant to be appointed by Contractor in connection with such claim and (b) prior to commencing any litigation with respect to such claim. Litigation between Contractor and a Subcontractor shall be jointly managed by Contractor and Owner. Contractor shall not settle any claim arising under a Subcontract without Owner’s prior approval.

 

23.2

CONTRACTOR RESPONSIBLE FOR WORK.

Contractor is responsible for each of the various parts of the Work, so that all items thereof conform in all respects to the requirements of this Agreement, regardless of any failure of any Subcontractor to perform, any disagreement between any Subcontractors, or any disagreement between any Subcontractors, on the one hand, and Contractor or Owner. Contractor shall furnish such information relative to its Subcontractors, including copies of unpriced (and with respect to the Reimbursable Work, all priced) Subcontracts as Owner may reasonably request. Without the express written consent of Owner, nothing contained herein or in any Subcontract awarded by Contractor shall create any contractual relationship between Owner and any Subcontractor. Contractor shall require that all Subcontractors release and waive (to the extent permitted by applicable Law) any and all rights against Owner and the Lenders for recovery of payment of any moneys for compensation for the portion of the Work performed by them.

 

23.3

ASSIGNMENT.

23.3.1 Subject to Section 23.3.2, Contractor hereby assigns to Owner (and Owner’s permitted assigns) all its interest in any Subcontracts (or any portion thereof to the extent such Subcontracts also relate to other projects of Contractor) now existing or hereafter entered into by Contractor for performance of any part of the Work, which assignment will be effective upon acceptance by Owner in writing and only as to those Subcontracts which Owner designates in said writing.

23.3.2 Owner shall not have the right to exercise any right to assignment of any Subcontract pursuant to Section 23.3.1 unless and until (a) any obligation by any Subcontractor under any Subcontract extends beyond the expiration of this Agreement, including the Warranty Period, (b) Owner has elected to terminate this Agreement in accordance with the terms hereof or (c) with respect to the Work, Contractor has failed to perform any of its material obligations or correct Defects and Deficiencies under this Agreement to which such Subcontract relates.

23.3.3 Each Subcontract entered into by Contractor with respect to the Work shall contain a provision permitting its assignment to Owner or the Lenders upon Owner’s written request (following the occurrence of any of the events described in Section 23.3.2).

 

90


Execution Version

 

24.

LABOR RELATIONS.

 

24.1

GENERAL MANAGEMENT OF EMPLOYEES.

Contractor shall exercise its management rights in performing the Work, either specifically detailed in, or not expressly limited by, applicable collective bargaining agreement(s). Subject to Section 5.2, such management rights shall be deemed to include the rights to: hire, discharge, promote and transfer employees; to select and remove foremen or other persons at other levels of supervision; to establish and enforce reasonable standards of productivity; to introduce, to the extent feasible, labor-saving equipment and materials; to determine the number of craftsmen necessary to perform a task, job or other work required with respect to the Facility; and to establish, maintain and enforce rules and regulations conducive to efficient and productive operations.

 

24.2

WAGES AND CONDITIONS.

Contractor shall make its own arrangements for the engagement of all staff and labor, local or otherwise, and for their payment, housing, feeding and transport. Contractor shall pay rates of wages, and observe conditions of labor, not materially different than those established for the trade or industry where the work is carried out, and shall comply with all Laws relating to wages, hours, working conditions and other employer/employee-related matters pertaining to its employees. In addition, Contractor shall certify to the reasonable satisfaction of Owner that all social benefit payments related to the wages of all workers employed directly or indirectly by it and its Subcontractors have been timely paid in full.

 

24.3

VIOLATIONS.

Contractor shall promptly notify Owner of any violations, and the actions to be taken or planned to resolve the violations, of collective bargaining agreements and jurisdictional disputes in connection with the Work including the filing of appropriate processes with any court or administrative agency having jurisdiction to settle, enjoin or award damages resulting from such violations of collective bargaining agreements or jurisdictional disputes.

 

24.4

DISPUTES.

Contractor shall undertake promptly all reasonable efforts to prevent or resolve any strikes or other labor disputes among its employees or the employees of Subcontractors. If a strike or other labor dispute occurs, Contractor shall take all reasonable actions to minimize any resulting disruption of the progress of the Work. Contractor shall advise Owner promptly, in writing, of any actual, anticipated or threatened labor dispute that might affect the performance of the Work by Contractor or by any Subcontractors and will keep Owner informed on a daily basis of the status of the dispute resolution. Notwithstanding the foregoing, the settlement of strikes, walkouts, lockouts or other labor disputes shall be at the sole discretion of the Party having the difficulty. Nothing in this Article 24 shall be deemed to amend the definition of “Force Majeure Event.”

 

24.5

STATUTORY EMPLOYER.

Notwithstanding anything to the contrary contained herein, in all cases where Contractor’s employees (meaning Contractor’s direct, borrowed, special or statutory employees) are covered

 

91


Execution Version

 

by the Louisiana Worker’s Compensation Act, La. R.S. 23:1021 et seq., Owner and Contractor agree that Owner shall be and hereby is designated as the statutory employer of Contractor’s direct, borrowed, special and statutory employees, pursuant to La. R.S. 23:1061(A)(3). Owner and Contractor further agree that the Work is an integral part of and essential to Owner’s ability to generate its goods, products and services. This provision is included for the sole purpose of establishing a statutory employer relationship to gain the benefits expressed in La. R.S. 23:1061, and is not intended to create an employer/employee relationship for any other purpose. Nothing contained in this Section 24.5 shall be construed to establish any relationship or status that is inconsistent with Article 37. In the event that Owner is required to pay worker’s compensation benefits to Contractor’s direct, borrowed, special or statutory employees, whether as a statutory employer pursuant to La. R.S. 23:1061 or as a special employer pursuant to La. R.S. 23:1031(C), Owner shall be entitled to reimbursement from Contractor for any such benefit payments. Neither Contractor nor its underwriters shall be entitled to seek contribution from Owner for any worker’s compensation benefits payments made on behalf of any of Contractor’s direct, borrowed, special or statutory employees for purposes of La. R.S. 23:1031(C).

 

24.6

LOCAL LABOR.

Contractor shall use commercially reasonable efforts to attract and retain local labor personnel for the Work and to utilize local Subcontractors whenever possible and cost effective. Contractor agrees to use good faith efforts to award Subcontracts to Subcontractors based in the State of Louisiana and to hire personnel to perform the Work that live in the State of Louisiana.

 

24.7

COMMUNITY IMPACTS.

Contractor shall use reasonable efforts to assist Owner in creating, assessing and carrying out programs which shall, during all phases of the Work, minimize the impacts upon the host community caused by the construction of the Facility. Such programs shall include sequencing of the Work so as to reasonably minimize the impacts of noise and dust at and around the Job Site.

 

25.

TITLE AND RISK OF LOSS.

 

25.1

TRANSFER OF TITLE.

25.1.1 Contractor warrants and guarantees to Owner good and legal title to the Materials and the Work, and shall deliver and convey ownership of the Materials and the Work free and clear of any and all liens, claims, security interest and other encumbrances, when title thereto passes to Owner. Title to all or any portion of the Materials shall pass to Owner upon the earliest of the following:

(a) the occurrence of any event by which, under applicable Laws, title passes from Contractor or Subcontractors providing such Materials;

(b) the date that such Materials are delivered to a shipper for shipment (whether by ship, air, rail, truck or otherwise and whether directly or indirectly) to the Job Site;

(c) the date that such Materials are delivered to the Job Site; and

(d) the date of termination of this Agreement, to the extent that Contractor has title.

 

92


Execution Version

 

25.1.2 It is expressly understood and agreed, however, that (a) the passage of title shall not release Contractor from the Contractor’s responsibility to perform fully its obligations hereunder, and (b) in no event shall title to the Owner Furnished Equipment and Materials pass from Owner to Contractor, and Owner shall, at all times, retain title and ownership of the Owner Furnished Equipment and Materials.

 

25.2

RISK OF LOSS.

Notwithstanding passage of title as provided in Section 25.1, Contractor shall bear risk of loss of or damage to the Work and Materials in respect of which Owner has not assumed care, custody and control hereunder until the Facility Substantial Completion Date, but only to the extent (i) of any insurance proceeds actually received by Contractor from claims made under Owner’s Construction and Erection All Risk Insurance Policy or other Owner insurance policies; or (ii) that such loss or damage results from the gross negligence or willful misconduct of Senior Supervisory Personnel or the willful misconduct of Contractor, its agents or Affiliates, workers, Senior Supervisory Personnel, Subcontractors and suppliers or the employees of each.

 

25.3

PROTECTION OF OWNER.

For the purpose of protecting Owner’s interest in all Materials and Owner Furnished Equipment and Materials delivered to the Job Site with respect to which title has passed to Owner but which remain in the possession of another party, Contractor shall take or cause to be taken all steps necessary under the Laws of the appropriate jurisdiction(s) to protect Owner’s title and to protect Owner against claims by other parties with respect thereto.

 

26.

INSURANCE.

 

26.1

IN GENERAL.

26.1.1 Contractor and Owner shall procure and maintain the insurance enumerated in this Article 26 as being applicable to it. The provisions of this Article 26 do not modify or change or abrogate any responsibility of Owner or Contractor or any Subcontractor stated elsewhere herein. Neither Owner nor Contractor assumes responsibility for the solvency of any insurer or the failure of any insurer to settle any claim. Contractor shall remain responsible for uninsured losses and deductible amounts under the policies to be provided by Contractor and, with respect to losses arising due to Contractor’s or its Subcontractor’s gross negligence or willful misconduct of Senior Supervisory Personnel, under the policies to be provided by Owner until the Facility Substantial Completion Date, and Owner shall become responsible for such losses and deductibles occurring thereafter.

26.1.2 Contractor shall provide the insurance set forth in Section 26.2 with properly licensed insurance carriers and evidence thereof in a form reasonably satisfactory to Owner and the Lenders’ insurance advisors, which insurance carriers shall be (a) rated A- or higher (with a financial size category of at least FSC VII) by A.M. Best’s Key Rating Guide, (b) rated A or higher by Standard and Poor’s or (c) satisfactory to Owner and the Lenders’ insurance advisor, in their

 

93


Execution Version

 

sole discretion. Owner shall provide the insurance set forth in Section 26.3 with properly licensed insurance carriers and evidence thereof and that are reinsured with reinsurers that are (i) rated A-or higher (with a financial size category of at least FSC VII) by A.M. Best’s Key Rating Guide or (ii) rated A or higher by Standard and Poor’s. Subject to Section 26.3.1 the Notice to Proceed and any Limited Notice to Proceed shall not be effective until each of Owner and Contractor has provided to each other such satisfactory evidence of insurance. Each Party shall promptly provide written notification to the other Party if it becomes aware of any material change in, non-renewal or cancellation of insurance coverage that such Party is required to maintain hereunder.

26.1.3 All the liability policies (except workers’ compensation, employer’s liability and professional liability) of insurance shall be endorsed to provide a severability of interests or cross liability clause to the benefit of each additional insured.

26.1.4 If any loss or damage to the Work (on or off the Job Site) is sustained, Contractor shall, at the request of Owner, act on behalf of itself and Owner for the purpose of adjusting the amount of the loss with the insurer. Contractor shall (a) replace or repair any such loss or damage and complete the Work in accordance with this Agreement and (b) take such action as may be reasonable and necessary to mitigate the amount of any such loss. Owner and, at the request of Owner, Contractor shall use commercially reasonable efforts for the benefit of the Parties to pursue all claims for loss or damage to property under the policies required to be provided by Owner pursuant to Section 26.3 that exceed the deductible amounts of such policies. As soon as practicable following a loss event, Contractor, Owner and the assigned loss adjuster shall meet to review the loss or damage and determine the course of action required to remedy the loss or damage. To the extent possible, Contractor and Owner shall determine with the loss adjuster the extent of loss or damage and the level of insurance coverage applicable to such loss or damage. Contractor shall cooperate with and provide the loss adjuster information relevant to the loss or damage, the schedule impact estimates of remediation, and any other reasonable information sought by insurers concerning the loss event. Contractor shall keep Owner reasonably informed of the status of claims negotiations with the insurer for which Contractor is, at the request of Owner, responsible under the Construction and Erection All Risk insurance required to be obtained by Owner pursuant to Section 26.3.1. For the avoidance of doubt, Owner shall remain the sole authority on any decisions related to claims handling, coordination and acceptance of payment on all Owner-procured insurance policies. Advance payments under the applicable insurance policy may be requested of insurers in order to facilitate cash flow and in no event shall Contractor be relieved of its obligation to repair and replace the loss or damage if such advance is not made.

26.1.5 Subject to the requirements and limitations set forth in Section 26.1.4, (a) Contractor shall include with each Request for Payment any amounts payable by Owner pursuant to this Section 26.1.5 and (b) provided that Contractor comply with all requirements for payment set forth herein, Owner shall pay such amounts in accordance with the terms of this Agreement.

 

26.2

POLICIES TO BE OBTAINED BY CONTRACTOR.

26.2.1 Except for the Construction and Erection All Risk insurance required to be provided by Owner pursuant to Section 26.3.1(a) and Commercial General Liability insurance required to be provided by Owner pursuant to Section 26.3.1(b), Contractor shall obtain and maintain in full

 

94


Execution Version

 

force and effect, and shall require, as applicable, Subcontractors to procure and maintain in full force and effect, the following insurance:

(a) General liability insurance written on ISO occurrence form CG 00 01 or equivalent policy wording covering all activities of Contractor other than the Work at the Job Site, and shall include Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer as additional insureds on a primary and noncontributory basis with respect to Work performed outside the Job Site, to the extent of the indemnity obligations assumed by Contractor under this Agreement. Such insurance shall be written in an amount of [***] per occurrence and [***] annual aggregate including a [***] aggregate limit for products and completed operations. Such insurance shall be endorsed to include coverage for products and completed operations for ten (10) years after the Facility Substantial Completion Date or the statute of repose, whichever is less. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed by Contractor under this Agreement;

(b) Workers Compensation, and if applicable, United Longshore and Harbor Workers Compensation Act insurance and Jones Act coverage, or similar insurance in the form prescribed by relevant laws and insuring against work related losses and claims arising in connection with the performance of the Work by Contractor. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed under this Agreement by Contractor;

(c) Employer’s Liability with limits available under a primary or excess policy equal to the equivalent of [***] per accident/occurrence or such higher limit as may be required by Laws. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed under this Agreement by Contractor;

(d) Automobile Liability Insurance applicable to all owned, non-owned, hired and leased automotive equipment used in the performance of the Work, including contractual liability, with limits of [***] per accident/occurrence combined single limit including Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing

 

95


Execution Version

 

documents and the Independent Engineer as additional insureds on a primary and noncontributory basis to the extent of the indemnity obligations assumed under this Agreement by Contractor. Such insurance shall contain a waiver of subrogation in favor of Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer to the extent of the indemnity obligations assumed under this Agreement by Contractor;

(e) Umbrella/Excess Liability Insurance providing coverage over the underlying insurance required in Sections 26.2.1(a), 26.2.1(c), and 26.2.1(d) with limits of [***] per occurrence and in the annual aggregate. Such insurance shall include Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer as additional insureds on a primary and noncontributory basis with respect to Work performed outside the Job Site and include a waiver of subrogation in favor of such additional insureds, to the extent of the indemnity obligations assumed by Contractor under this Agreement;

(f) Contractor shall maintain or require to be maintained Professional Liability Insurance, on account of any errors or omissions of Contractor and Subcontractors involved in Work contracted hereunder with liability limits of insurance of [***] per claim and [***] in the aggregate during construction and for a five (5) year period after Final Completion;

(g) Contractor shall either (i) maintain or require to be maintained project specific Pollution Liability Insurance, for any event caused or exacerbated by actions or inactions of Contractor and Subcontractors involved in Work contracted hereunder with liability limits of insurance of at least [***] per occurrence and [***] in the annual aggregate during construction and include Owner, its parent, owners, subsidiaries and affiliate companies, their officers, agents, managers employees, directors, joint owners, the Lenders (individually), any other entity required of Owner in its financing documents and the Independent Engineer as additional insureds on a primary and non-contributory basis, and include a waiver of subrogation in favor of such additional insureds, or (ii) provide Owner and the Lenders with such security as is deemed sufficient by such parties to cover any such errors and omissions; and

(h) For all vessels owned, operated, chartered, or brokered by or for Contractor or any of the Subcontractors in connection with the Work, Contractor shall carry or require the owner or operator of such vessels to carry watercraft insurance, as follows: (i) Hull Insurance for full fair value; (ii) Protection and Indemnity Insurance under Form SP-23 (Revised 1/56), or most recent version, to cover liabilities arising out of the ownership, operation and use of any vessel with liability limits of insurance of [***] per occurrence, including (y) pollution and environmental liability insurance upon such vessels for damages, cleanup and restoration costs, in amount no less than those limits required by applicable Law and coverage for crew and personnel on such vessels,

 

96


Execution Version

 

with no exclusion for activities arising from the use of remote operated vehicles and submarines and diving operations (if these operations are to be performed under this Agreement), and (z) including collision and tower’s liability, cargo legal liability (to the extent applicable), and coverage for liabilities for the removal of wreck or debris as compulsory under statute or as requested by applicable Government Authorities. Insurers shall waive any right to limit liability to the value of the vessel, but only with respect to Owner indemnified parties, whichever is applicable, and the phrase “as owner of vessel named herein” and all similar phrases purporting to limit the insurer’s liability to that of an owner shall be deleted. The coverage in clause (y) regarding pollution and environmental liability insurance for damages, cleanup and restoration costs (in amount no less than those limits required by applicable Law) may be provided under a marine pollution liability policy; provided that such policy provides the same coverage and limits that would be provided under the protection and indemnity insurance. Should the Work necessitate the use of remotely operated vehicles or dredging, this protection and indemnity insurance shall include a specialist operation endorsement; and (iii) Charterer’s Legal Liability Insurance to cover liabilities arising out of operation and use of any time or voyage chartered vessel including coverage for contractual liability for those liabilities assumed by Contractor herein with liability limits of insurance of [***] per occurrence. The insurance listed in clauses (y) and (z) above shall provide that seaworthiness of vessels used to perform Work hereunder is accepted by insurers (or that insurers shall waive in favor of Owner indemnified parties, the vessel owner’s and/or Contractor’s warranty of seaworthiness).

26.2.2 [Reserved].

26.2.3 Contractor shall be responsible for additional costs associated with modifying any inadequate coverage, terms and conditions to meet the requirements of this Section 26.2. Contractor shall comply with all the conditions and requirements provided for in its insurance policies and to the extent Contractor has been notified in writing of such conditions and requirements the policies required to be maintained by Owner pursuant to Section 26.3. Contractor shall make no material adverse alteration to the terms of any insurance required herein without the prior written approval of Owner and the Independent Engineer. If an insurer makes (or purports to make) any such alteration, Contractor shall notify Owner immediately.

26.2.4 Contractor shall require all insurers under Contractor’s insurance policies to provide Owner and such other interested Persons as may be designated by Owner with certificates of insurance, in form and substance reasonably acceptable to Owner, evidencing and describing the insurance policies and endorsements maintained hereunder prior to commencement of the Work, or upon issuance of such policies, if earlier, and prior to each issuance anniversary date throughout the term of this Agreement. The certificates of insurance shall evidence and describe the insurance policies and endorsements. Notwithstanding anything to the contrary contained herein, evidence of such coverage shall be provided to Owner as a condition precedent to the commencement of the Work.

26.2.5 In respect of all of the Contractor’s insurance policies, Contractor shall, on or before the Notice to Proceed Date and as may be requested by Owner from time to time, produce the Contractor’s certificates of insurance, and required endorsements. If policies have been secured on a project specific basis, Contractor shall provide the actual policy upon written request by Owner.

 

97


Execution Version

 

26.2.6 Before permitting any of its Subcontractors to perform any Work at the Job Site, Contractor shall obtain a certificate of insurance from each such Subcontractor evidencing that such Subcontractor has obtained the insurance required of Subcontractors by Contractor, such insurance at a minimum to include Workers Compensation, and if applicable, United Longshore and Harbor Workers Compensation Act insurance and Jones Act coverage, general liability, employer’s liability and umbrella/excess liability insurance and, with respect to Subcontractors that charter a vessel for the purpose of their work, the insurance described in Section 26.2.1(g). Policies provided by Subcontractors shall be in amounts and upon conditions as are customarily and normally provided for work similar to the Work. Contractor shall use reasonable efforts to cause all Major Subcontractors to include in their respective insurance policies a waiver of any right of subrogation of the insurers thereunder against Owner, the Lenders, the Independent Engineer and Contractor, and any right of the insurers to set off or counterclaim, offset or any other deduction, whether by attachment or otherwise, in respect of any liability of any such Person insured under such policy.

26.2.7 If Contractor shall fail to obtain and keep in force insurance required pursuant to this Section 26.2, Owner may, without limiting any other remedy it may have, obtain and keep in force any such insurance and pay such premium or premiums as may be necessary for that purpose and recover from Contractor whether by way of deduction, offset or otherwise the cost of obtaining and maintaining such insurance.

26.2.8 Except as directed by Owner, Contractor shall be responsible for managing and administering all of Contractor’s insurance policies, including the payment of all deductibles pursuant to Section 26.1.1 and self-insured retention amounts, the filing of all claims and the taking of all necessary and proper steps to collect any proceeds on behalf of the relevant insured Person. Contractor shall at all times keep Owner informed of the filing and progress of any claim arising out of or relating to the Work. If Contractor shall fail to perform these responsibilities, upon reasonable written notice Owner may take such action as it determines appropriate under the circumstances. In the event Contractor collects proceeds on behalf of other Persons, it shall ensure that these are paid directly from the insurers to the relevant Person and, in the event that it receives any such proceeds, it shall, unless otherwise directed by Owner, pay such proceed to such Party forthwith and prior thereto, hold the same in trust for the recipient.

26.2.9 All equipment, tools, supplies and materials belonging to Contractor or any Subcontractor and used by Contractor or such Subcontractor for the performance of the Work and not to be incorporated into or to be left at the Facility shall be brought to and kept at the Job Site at the cost and risk of Contractor or such Subcontractor, and Owner shall not be liable for loss or damage thereto and any insurance policies carried by Contractor or Subcontractors shall waive the insurer’s right to subrogation against Owner, the Lenders and the Independent Engineer, and their respective assignees, subsidiaries, Affiliates and employees. Contractor shall obtain, or shall cause Subcontractors to obtain, adequate insurance to cover any construction tools and equipment leased from Third Parties.

 

98


Execution Version

 

26.3

POLICIES TO BE OBTAINED BY OWNER.

26.3.1 From and after the earlier of the Notice to Proceed Date and such other date as the Parties may mutually agree upon in writing (whether earlier or later) through Final Completion, Owner shall obtain and maintain in full force and effect at its cost, the following insurance with respect to the procurement, construction, erection, Pre-Commissioning, Commissioning, testing and pre-completion operation of the Materials, the Work at the Job Site and the Facility; provided that Owner shall not be obligated to obtain Construction and Erection All Risk insurance before the date upon which Contractor or any Subcontractor will begin Work at, or deliver Materials to, the Job Site:

(a) Construction and Erection All Risk insurance (excluding Contractor’s and Subcontractors’ equipment and property not intended to be installed into the Facility). Such insurance policy shall be written on a replacement cost basis and be in the joint names of Owner and the Lenders as named insureds and Contractor and Subcontractors as additional insureds with a waiver of the insurer’s rights of subrogation in favor of all such named insureds and additional insureds. The deductible under such insurance shall be consistent with the terms reasonably and commercially available in the insurance marketplace considering the equipment and maturity of its design and location. The policy shall also provide, in amounts reasonably acceptable to the Lenders, (i) coverage for removal of debris, (ii) transit coverage with worldwide coverage territory including the continental boundaries of the United States of America and inland waterways, not including air and ocean marine coverage, (iii) off-site storage coverage, (iv) pollution clean-up and removal (with per occurrence and policy aggregate sublimits), (v) professional fees, (vi) operational and performance testing, (vii) earth movement, flood, named windstorm, expediting expense (with per occurrence and policy aggregate sublimits), (viii) minimization of loss expense, (ix) design defect clause no more restrictive than LEG 2/96, (x) 50/50 hidden damage clause, (xi) advance payment clause and (xii) fire department charges clause. The deductible and any self-insured retentions under such insurance shall be for Owner’s account. Owner may, in its sole discretion, carry and maintain Delay in Commissioning or Start-up insurance covering at least Owner’s debt service payments (principal and interest), and as the Lenders may require, continuous fixed expenses and additional expenses incurred as a result of loss or damage covered under the insurance provided pursuant to Sections 26.3.1(a) and 26.3.1(c). Any recovery under the Delay in Commissioning or Start-up coverage will accrue to the benefit of Owner. If an event or events occur that may be covered by the Delay in Commissioning or Start-up insurance, it shall be Owner’s sole option to decide whether to file a claim under such Delay in Commissioning or Start-up insurance.

(b) Owner Controlled Insurance Program for Commercial General Liability insurance with a limit of at least [***] per occurrence and in the aggregate for bodily injury and property damage at the Job Site. Such coverage shall name Owner, the Lenders, Contractor and Subcontractor as insureds with a waiver of subrogation in favor of any insured and shall include a severability of interest and cross liability provision. Coverage may be arranged in combination of primary and excess coverage. The deductible and any self-insured retentions shall be for Owner’s account. Owner’s procurement and provision of this insurance shall in no way relieve

 

99


Execution Version

 

Contractor or any Subcontractor of any responsibility or liability under this Agreement, any applicable law, statute, regulation or order. Notwithstanding any provision to the contrary, the coverage provided by the Owner Controlled Insurance Program shall be primary and non-contributory to any insurance provided or maintained by Contractor or its Subcontractors.

(c) Subject to prevailing terms in the insurance marketplace, air and ocean cargo coverage for all Materials shipped to the Job Site (other than locally procured Materials) and insuring the interest of Owner, the Lenders, Contractor and Subcontractors (however excluding ship-owners, charterers, freight-forwarders, haulers and riggers) written on a warehouse to final destination basis from customary standard ICC (A) clause “all risk” air and marine perils while in transit. Such policy shall be written on CIF + 10% or equivalent or replacement cost basis or in such other amounts acceptable to Owner, the Lenders and Contractor, and shall be subject to a per conveyance limit equivalent to the maximum value of the shipment. Such maximum value shall be determined before the inception of the policy. The deductibles and any self-insured retentions under such insurance shall be for Owner’s account. Contractor shall provide Owner with schedules and Notices of air and marine shipments pursuant to Section 3.8.18. Owner shall be responsible for any required load survey costs incurred in connection with any shipment of Materials or equipment for Work performed under this Agreement, including but not limited to complying with Loss Control Warranty Wordings.

(d) Upon the LNG Production System Substantial Completion of each LNG Production System, Owner shall have in place a Commercial Property Policy for such LNG Production System and corresponding LNG Production System Handover Package from the time care, custody and control of such LNG Production System Handover Package transfers from Contractor to Owner in accordance with Section 18.1.3. Such policy shall contain a waiver of subrogation in favor of Contractor and its Subcontractors.

26.3.2 Owner shall also provide Contractor with satisfactory evidence of the existence of insurance policies obtained by Owner prior to an effective Notice to Proceed Date and copies of the policies of insurance obtained by Owner not later than thirty (30) days following the Notice to Proceed Date.

26.3.3 Insurance required to be maintained by Owner hereunder shall be subject to standard sublimits and exclusions reasonably commercially available in the insurance marketplace. In addition, if other coverage limits or deductibles described in this Section 26.3 are not available at commercially reasonable rates, Owner shall notify Contractor and the Parties shall discuss appropriate alternative coverage limits and/or deductibles.

26.3.4 All insurance referred to in this or any other Section of this Agreement shall be subject to review and acceptance by the Lenders, and Contractor shall assist as necessary in arranging and maintaining all such insurance and shall not do or omit to do anything that may cause such policy to be invalidated or a valid claim to be repudiated.

 

100


Execution Version

 

26.3.5 Each of Owner and Contractor shall also purchase insurance that may be statutorily required from time to time and/or enroll employees in such state schemes as may be so required at each Party’s own expense during the term of this Agreement.

26.3.6 Contractor shall cooperate with Owner and its insurers to provide any information requested by the insurers necessary to maintain, manage or obtain an extension to the insurance policies.

 

27.

CONFIDENTIAL TREATMENT OF PROPRIETARY INFORMATION; RELIANCE ON INFORMATION.

 

27.1

CONFIDENTIAL TREATMENT.

27.1.1 Contractor covenants and warrants (on behalf of its Representatives) that it shall not (without in each instance obtaining Owner’s prior written consent) disclose, make commercial or other use of, or give or sell to any Person any non-public information regarding Owner, its Affiliates or the Facility (including commercially sensitive information related to the transactions contemplated hereby) (“Confidential Information”); provided, however, that Contractor may disclose such Confidential Information (but only to the extent necessary) (a) to its Representatives, Subcontractors and suppliers who have a need to know such Confidential Information, (b) to its counsel, (c) to any Government Authority to the extent required by Law to be disclosed, (d) under seal in connection with any arbitration, mediation or litigation or (e) to the Lenders or the Independent Engineer in connection with the Financing or insurance underwriters in connection with the Work; provided, further, that any Confidential Information disclosed pursuant to clauses (a), (b), (d) and (e) shall not be disclosed unless (i) the recipient is informed as to the confidential nature of such information, (ii) the recipient agrees to a separate confidentiality agreement with terms and conditions as least as restrictive as this Section 27.1.1 as a condition to the receipt of such Confidential Information and (iii) the disclosing Party remains liable for any breach of this Section 27.1.1 if the breach is caused by the disclosing party or its officers or employees; provided, further, that prior to any disclosure of Confidential Information pursuant to clause (c), Contractor shall give reasonable notice to Owner of the information required to be disclosed and, to the extent reasonably capable under applicable Law and the circumstances surrounding the disclosure, shall provide Owner with an opportunity to take appropriate steps Owner believes are necessary to protect the confidentiality and/or proprietary nature of its Confidential Information. Contractor shall not, nor shall it permit any of its subsidiaries or Affiliates to, issue or cause the publication of any press release or other public statements, announcements or disclosure with respect to this Agreement or the transactions contemplated hereby, or otherwise use Owner’s trademarks, service marks, trade names, logos, domain names, or other indicia of source, association, or sponsorship, without the written consent of Owner. The duration of the obligations stated in this Section 27.1 shall be (x) for Confidential Information that is identified by a Party to be a trade secret, for so long as such Confidential Information remains confidential, and (y) for all other Confidential Information, for a period of ten (10) years after the expiration or termination of this Agreement. Information shall not be deemed to be “Confidential Information” where: (A) it is or becomes public information or otherwise generally available to the public through no act of or failure to act by Contractor; (B) it was, prior to the Effective Date, already in the possession of Contractor and was not received by Contractor directly or indirectly from Owner and is not subject to a confidentiality agreement; (C) it is rightfully received by Contractor from a third party who is not

 

101


Execution Version

 

prohibited from disclosing it to Contractor and is not breaching any agreement by disclosing it to Contractor; or (D) was independently developed by the Contractor without the use of any Confidential Information of Owner. Specific information shall not be deemed to be within the exceptions of the previous sentence merely because it is embraced by more general information within such exceptions, nor shall a combination of features be deemed to be within such exceptions merely because the individual features are within such exceptions. Contractor acknowledges that in the event of a breach of any of the terms contained in this Article 27, Owner may suffer irreparable harm for which remedies at law, including damages, would be inadequate, and that Owner shall be entitled to seek equitable relief therefor by injunction, in addition to any and all rights and remedies available to it at law and in equity, without the requirement of posting a bond.

27.1.2 Without limiting Section 27.1.3, Owner covenants and warrants (on behalf of its Representatives and the Independent Engineer ) that it shall not (without in each instance obtaining Contractor’s prior written consent) disclose, make commercial or give or sell to any Person any non-public information regarding the Contractor’s reimbursable or unit rates, the liability and liquidated damages caps set forth in this Agreement, Contractor Intellectual Property, or other commercial information of Contractor unrelated to the Facility, the Work, this Agreement and not required to be provided or licensed to Owner under Article 29 (collectively, “Contractor Confidential Information”); provided, however, that Owner may disclose the Contractor Confidential Information listed in (i) above (but only to the extent necessary) to the parties listed in Section 27.1.1 (a) through (e) above, applied on a mutatis mutandis basis, and Owner’s existing or potential LNG offtakers and buyers, and so long as the recipient agrees to maintain the confidentiality of Contractor Confidential Information on terms and conditions as least as restrictive as those set forth herein; and provided, further, that, except as necessary for Owner to invoice any Owner Contractor for corrective or remedial work performed by Contractor, Owner shall not directly or indirectly provide the Contractor Confidential Information to any engineering, construction and procurement contractor (including UOP, BH and CB&I) that provides engineering, construction and procurement services for chemical or LNG facilities as a substantial part of its business without the prior written consent of the Contractor. Section 27.1.2 shall apply on a mutatis mutandis basis to Contractor Confidential Information. Owner acknowledges that in the event of a breach of any of the terms contained in this Article 27, Contractor may suffer irreparable harm for which remedies at law, including damages, would be inadequate, and that Contractor shall be entitled to seek equitable relief therefor by injunction, in addition to any and all rights and remedies available to it at law and in equity, without the requirement of posting a bond. Information shall not be deemed to be “Contractor Confidential Information” where: (A) it is or becomes public information or otherwise generally available to the public through no act of or failure to act by Owner; (B) it was, prior to the Effective Date, already in the possession of Owner and was not received by Owner directly or indirectly from Contractor and is not subject to a confidentiality agreement; (C) it is rightfully received by Owner from a third party who is not prohibited from disclosing it to Owner and is not breaching any agreement by disclosing it to Owner; or (D) was independently developed by Owner without the use of any Contractor Confidential Information. Specific information shall not be deemed to be within the exceptions of the previous sentence merely because it is embraced by more general information within such exceptions, nor shall a combination of features be deemed to be within such exceptions merely because the individual features are within such exceptions.

 

102


Execution Version

 

27.1.3 All right and title to, and interest in, the Confidential Information shall remain with Owner. All Confidential Information obtained, developed or created by or for Contractor exclusively for the Facility, including copies thereof, is and shall be the sole and exclusive property of Owner (except Contractor Intellectual Property contained therein, which will be governed by Section 29.2), whether delivered to Owner or not, and Contractor agrees to assign and hereby assigns any and all right, title, and interest therein it may have to Owner, in each case subject to Section 29.1. No right or license is granted to Contractor or any third party respecting the use of Confidential Information by virtue of this Agreement, except to the limited extent required for the Contractor’s performance of its obligations hereunder. Contractor shall cease all use of and deliver to Owner or destroy all Confidential Information, including all copies thereof, upon Owner’s request, provided Contractor may retain a copy of the Confidential Information to comply with applicable Law, and to the extent any routine computer back-up procedures create copies in the associated back-up or archival computer storage system. Such copies retained shall remain subject to the provisions of this Agreement.

 

27.2

RELIANCE ON INFORMATION.

Subject to Article 29, Owner shall have unrestricted use of Drawings and Specifications provided to Owner pursuant to this Agreement.

 

28.

REPRESENTATIONS AND WARRANTIES.

 

28.1

OWNER REPRESENTATIONS AND WARRANTIES.

Owner represents and warrants that as of the Effective Date:

28.1.1 Owner is a limited liability company duly organized and validly existing in good standing under the laws of the State of Delaware and has all necessary power and authority to enter into and perform its obligations under this Agreement;

28.1.2 Each of the execution, delivery and performance by Owner of this Agreement has been duly authorized by all necessary action on the part of Owner and does not contravene or constitute a default under any provision of applicable Law, the constituting documents or the certificate of formation of Owner or of any other agreement, judgment, injunction, order, decree or other instrument binding upon Owner; and

28.1.3 Owner has duly executed and delivered this Agreement and, assuming the due authorization, execution and delivery thereof by Contractor, this Agreement constitutes (or when so executed and delivered will constitute) a valid and binding obligation of Owner enforceable against Owner in accordance with its terms, except that (a) such enforceability may be limited by applicable bankruptcy, insolvency, reorganization, liquidation, moratorium or similar laws affecting creditors’ rights generally and (b) the application of general equitable principles may limit the availability of certain remedies.

 

28.2

CONTRACTOR REPRESENTATIONS AND WARRANTIES.

Contractor represents and warrants that as of the Effective Date:

 

103


Execution Version

 

28.2.1 It is a corporation duly organized and validly existing in good standing under the laws of Texas, and has all necessary power and authority to carry on its business as presently conducted, to own or hold under lease its properties and to enter into and perform its obligations under this Agreement;

28.2.2 Each of the execution, delivery and performance by it of this Agreement has been duly authorized by all necessary action on its part, does not require any approval, except as has been heretofore obtained, of its board of directors or shareholders or any consent of or approval from any trustee, lessor or holder of any indebtedness or other obligation of it, except for such as have been duly obtained, and does not contravene or constitute a default under any provision of applicable Law, its constituting documents or by-laws or of any agreement, judgment, injunction, order, decree or other instrument binding upon it, or subject the Facility or any component part thereof or the Job Site or any portion thereof to any lien other than as contemplated or permitted by this Agreement; and it is in compliance with all applicable Laws (a) which govern its ability to perform its obligations under this Agreement or (b) the noncompliance with which would have a material adverse effect on it;

28.2.3 Neither the execution and delivery by it of this Agreement, nor the consummation by it of any of the transactions contemplated hereby, requires the consent or approval of, the giving of notice to, the registration with, the recording or filing of any document with, or the taking of any other action in respect of any Government Authority, except such as are not yet required, and it has no reason to believe that the same will not be readily obtainable in the ordinary course of business upon due application therefor, or which have been duly obtained and are in full force and effect;

28.2.4 It has duly executed and delivered this Agreement, and, assuming the due authorization, execution and delivery thereof by Owner, this Agreement constitutes (or when so executed and delivered will constitute) its valid and binding obligation, enforceable against it in accordance with its terms, except that (a) such enforceability may be limited by applicable bankruptcy, insolvency, reorganization, liquidation, moratorium or similar laws affecting creditors’ rights generally and (b) the application of general equitable principles may limit the availability of certain remedies;

28.2.5 Contractor has substantial experience and all the required skills and capacity necessary for the engineering, procurement and fabrication of Materials used in LNG export and liquefaction facilities comparable to the Facility, and is fully qualified to engineer, procure and construct the Work and otherwise perform the Work in accordance with this Agreement;

28.2.6 It understands that as background information and as an accommodation to it, prior to the Effective Date Owner may provide or may have provided it with copies of certain studies, reports or other information. It further acknowledges and agrees that (a) Owner makes no representations or warranties with respect to the accuracy of such documents or the information or opinions therein contained or expressed unless expressly stated herein (including any Exhibit hereto), (b) Owner shall not be liable to it in contract, tort or otherwise as a result of the use of such information by it, except as expressly provided herein and (c) except for the Relied Upon Information, it shall not rely upon such information without satisfying itself as to its accuracy and completeness;

 

104


Execution Version

 

28.2.7 It (a) has examined this Agreement, including all Exhibits attached hereto, thoroughly and become familiar with all its terms and provisions and to the best of its knowledge, it has reviewed all other documents and information necessary and available to it in order to ascertain the nature, location and scope of the Work, the character and accessibility of the Job Site and surrounding area, the existence of obstacles at the Job Site and surrounding area to the performance of the Work, the availability of facilities and utilities, and the location and character of any existing or adjacent work or structures, and based on such examination and review has no reason to believe that it will be unable to complete the Work in accordance with this Agreement and (b) expressly waives any claims for additional compensation, reimbursement, damages, liabilities or time extension in connection with such conditions, except as otherwise provided herein including Sections 3.3 and 12.4; and

28.2.8 Excluding any Intellectual Property rights that are granted or conveyed to Owner under the Owner Contracts (in respect of which no representations or warranties are made by Contractor), none of the Inventions, Materials or the design, engineering and other Work or services rendered by Contractor hereunder, nor the use or ownership thereof by Owner, infringes, as of the Effective Date or prior to Final Completion violates or constitutes a misappropriation of any third party Intellectual Property rights (including any trade secrets, proprietary rights, patents, or copyrights) or trademark, and Contractor further has all requisite rights to grant Owner such rights specified in Article 29.

 

29.

INTELLECTUAL PROPERTY AND LICENSES.

 

29.1

OWNERSHIP.

Contractor shall disclose promptly in writing to Owner all inventions, discoveries, developments and other Intellectual Property which it or its employees or agents (a) may make, create, develop, invent, conceive or first reduce to practice which are based on or derived from Confidential Information or other proprietary information received from Owner or (b) made, created, developed, invented, conceived or first reduced to practice hereunder for the purposes of the Work (but excluding Contractor Intellectual Property) ((a) and (b) collectively, “Inventions”). All right, title and interest (including all Intellectual Property rights other than Contractor Intellectual Property) in and to all such Inventions, as well as any Deliverables (including all Intellectual Property rights therein other than Contractor Intellectual Property) provided hereunder, shall be the sole and exclusive property of Owner, and Contractor agrees to assign and hereby assigns all such right, title, and interest in and to all such Inventions and Deliverables (including all Intellectual Property rights therein other than to Contractor Intellectual Property) to Owner. Contractor retains all right, title and interest to all Contractor Intellectual Property. Nothing in this Agreement grants to Contractor any right under or to Owner’s Intellectual Property.

 

29.2

LICENSES.

29.2.1 From the receipt of the first payment on or following the Notice to Proceed Date, Contractor hereby grants to Owner and its Affiliates (and shall procure for Owner from any Subcontractors) a perpetual, irrevocable (so long as Owner has not been finally adjudged by court or arbitral tribunal to be in material breach of its payment obligations hereunder), royalty-free, transferable (limited to its Affiliates, any Lender exercising any step-in rights or any owner of the

 

105


Execution Version

 

Facility), worldwide, nonexclusive license in, to, and under the Contractor Intellectual Property to copy, modify, reproduce, distribute, practice, and otherwise utilize the same to the extent reasonably necessary for the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, reconstruction, alteration or modification of the Facility (including any portion, subsystem, unit or component thereof), but not including the right to grant sublicenses to third parties except in connection with and as necessary for the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem, unit or component thereof) or to accomplish an above-permitted transfer.

29.2.2 Contractor agrees to execute or have executed all documents, and to perform or have performed all lawful acts that Owner may deem reasonably desirable or necessary to perfect its (or its designee’s) ownership of or license(s) to which it is entitled pursuant to this Article 29.

29.2.3 Contractor shall, prior to directing any Subcontractors to perform any part of the Work, obtain a valid written assignment and license from each such Subcontractor covering the same items and on identical (or if identical terms cannot be obtained, despite Contractor’s commercial reasonably efforts to do so and so long as prior written notice is provided to Owner, equivalent) terms as those that obligate Contractor to the Owner as expressed in this Article 29.

 

29.3

DATA.

Subject to the retention by Contractor of all Contractor Intellectual Property, all Drawings and Specifications furnished or required to be furnished by Contractor to Owner in performing the Work (including all Intellectual Property rights therein) are and shall be the sole and exclusive property of Owner, and Contractor agrees to assign and hereby assigns all such right, title and interest in and to all such Drawings and Specifications (including all Intellectual Property rights therein, but excluding Contractor Intellectual Property) to Owner. From the Effective Date, Contractor grants to Owner, without limitation of Section 29.2.1, a perpetual, irrevocable (so long as Owner has not been finally adjudged by court or arbitral tribunal to be in material breach of its payment obligations hereunder), worldwide, nonexclusive, nontransferable (except to Owner’s Affiliates, any Lender exercising step-in rights or any owner of the Facility), royalty-free right to use all Intellectual Property included in the Drawings and Specifications (including technical information and software), that is not owned by Owner, all for the purpose of the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (including any portion, subsystem, unit or component thereof), but not including the right to grant sublicense to third parties except in connection with and as necessary for the completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem, unit or component thereof) or to accomplish an above-permitted transfer.

 

106


Execution Version

 

30.

INDEMNIFICATION.

 

30.1

CONTRACTOR INDEMNITY.

30.1.1 Contractor shall defend, indemnify, and hold the Owner Indemnitees harmless from and against any and all Losses incurred by any such Owner Indemnitees to the extent arising from or based on any Intellectual Property Claim. If any use, operation, or enjoyment of the Facility or any part thereof is the subject of an Intellectual Property Claim, then, in addition, Contractor shall promptly, but in no event later than thirty (30) days from the date of notice from Owner, commence action to remove such impediment, and thereafter shall diligently pursue removal of such impediment, (at Contractor’s option) by: (a) procuring for Owner, or reimbursing Owner for procuring, the right to continue using the subject of the Intellectual Property Claim; (b) modifying the subject of the Intellectual Property Claim to avoid the alleged infringement, disclosure, use, misappropriation or other violation, while maintaining substantially the same performance, quality and expected life satisfying the requirements of this Agreement, to the reasonable satisfaction of Owner; or (c) replacing the subject of the Intellectual Property Claim with service, Materials, Inventions, or other Work or Contractor Intellectual Property, as applicable, of comparable functionality and quality and satisfying the requirements of this Agreement, to the reasonable satisfaction of Owner, that avoids the alleged infringement, disclosure, use, misappropriation or other violation; provided that in no case shall Contractor take any action which materially and adversely affects Owner’s continued completion, design, construction, installation, operation, maintenance, repair, replacement, expansion, modification, alteration or reconstruction of the Facility (or any portion, subsystem or component thereof) without the prior written consent of Owner; and provided further, that in no event shall Contractor have such indemnity obligations or obligation to remove such impediment for any Intellectual Property Claim arising from or in connection with (i) the Owner Furnished Equipment and Materials or any written instruction, written information, designs, specifications, or other materials provided by Owner to Contractor, (ii) any action or omission of any Owner Contractor, or (iii) any modification of the Work directed by Owner or that was not authorized by Contractor. For the avoidance of doubt, Owner’s acceptance of the Materials, Deliverables, Inventions, and other equipment or any other component of the Work shall not be construed to relieve Contractor of any obligation hereunder. Owner shall, and shall cause other Owner Indemnitees to, agree to reasonably cooperate and assist Contractor in the defense of any Intellectual Property Claims, at Contractor’s cost. Any Owner Indemnitee that seeks to settle any Intellectual Property Claim shall seek the prior approval of Contractor, which approval shall not be unreasonably withheld, conditioned, or delayed, in respect of such settlement. Contractor shall not settle any Intellectual Property Claim that includes any non-monetary obligations without the prior approval of Owner, which approval shall not be unreasonably withheld, conditioned, or delayed, in respect of such settlement.

30.1.2 In addition to its indemnification, defense and hold harmless obligations contained elsewhere herein, to the fullest extent permitted by Law, Contractor assumes liability for, and agrees to indemnify, protect, save and hold harmless and defend each of the Owner Indemnitees from and against any and all Losses (including any strict liability, all fines and penalties as well as reasonable attorneys’ fees, consultant fees, experts’ fees and litigation expenses) of whatsoever kind and nature that may be imposed on, suffered or incurred by or asserted against any Owner Indemnitee in any way relating to or directly or indirectly arising out of (a) the presence, Release or threatened Release of any Hazardous Substance used, generated or handled by or brought to the

 

107


Execution Version

 

Job Site or disposed by or at the direction of Contractor or any Subcontractor (but in all cases, excluding (i) Pre-Existing Hazardous Substances (except to the extent of Contractor’s or its Subcontractors’ noncompliance with Section 3.8.46 or the gross negligence or willful misconduct in the handling, storage or transportation of any Pre-Existing Hazardous Substance after discovery of such Pre-Existing Hazardous Substance by Contractor or a Subcontractor); or (ii) claims arising out of Owner’s gross negligence or willful misconduct in the handling, storage or transportation of Hazardous Substances brought to the Site by Contractor), (b) bodily injuries (including wrongful death) or property damage of Third Parties (with respect to bodily injuries, “Third Parties” shall include Owner’s employees), to the extent caused by the negligent acts or omissions of Contractor, any worker or any Subcontractor or anyone for whose acts they may be liable arising in connection with the performance of the Work, (c) fines and penalties arising out of the violation by Contractor or any Subcontractor of: (i) any Permit held in its name or (ii) any applicable Law, (d) the vitiation of any Contractor provided insurance policies due to Contractor’s or any Subcontractor’s breach of any representation, declarations or conditions contained in any insurance policy, including the provision of false or misleading information, (e) Contractor or any Subcontractor terminating the employment of or removing from the Work any employee who fails to meet the requirements set forth in Section 5.1.2 following a request by Owner to have such employee removed from Work, or (f) claims by any Government Authority as a result of a failure by Contractor or any Subcontractor to pay Taxes for which it is responsible to pay or remit under this Agreement.

30.1.3 To the fullest extent permitted by Law, Contractor assumes liability for, and agrees to indemnify, protect, save and hold harmless and defend each of the Owner Indemnitees from and against any and all Losses (including any strict liability, as well as reasonable attorneys’ fees, consultant fees, experts’ fees and litigation expenses) of whatsoever kind and nature that may be imposed on, suffered or incurred by or asserted against any Owner Indemnitee to the extent arising from the negligence of Contractor or any Subcontractor or any other Person directly or indirectly employed by any of them hereunder for damage to or loss of the physical property of Owner or its Affiliates for which Owner or its Affiliate has assumed care, custody and control (excluding, for the avoidance of doubt, the Work for which Contractor has the risk of loss under Section 25.2 at the time the damage occurred); provided, however, Contractor’s and Subcontractor’s total liability hereunder for each occurrence of such damage or loss to such property shall not exceed [***] and Owner releases the Contractor Indemnitees and Subcontractors from any liability in excess of such amount, whether or not any such liability is claimed in contract, statute, equity, tort or otherwise and shall apply irrespective of negligence.

 

30.2

OWNER INDEMNITY.

Subject to Contractor’s indemnity obligations under Section 30.1, to the fullest extent permitted by Law, Owner assumes liability for, and agrees to indemnify, protect, defend, save and hold each of the Contractor Indemnitees harmless from and against any and all Losses (including any strict liability, as well as reasonable attorneys’ fees, consultant fees, experts’ fees and litigation expenses) of whatsoever kind and nature that may be imposed on, suffered or incurred by or asserted against any Contractor Indemnitee: (i) arising out of or due to a claim or action made by any third party (which third party shall not include any Contractor Indemnitee except with respect to bodily injury) to the extent caused by or arising directly from the negligence, gross negligence or willful misconduct of Owner, its Affiliates or Owner Contractors or their officers or employees

 

108


Execution Version

 

while engaged in the performance of any activities in connection with this Agreement and (ii) for any claims arising out of Pre-Existing Hazardous Substances on the Job Site (except to the extent Contractor is otherwise liable as set forth in Section 30.1.2(a)(i)).

 

30.3

ACTIONS BY EMPLOYEES.

In any and all claims against any indemnified person by any employee of Contractor or any Subcontractor or by anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, the indemnification obligation stated above shall not be limited in any way by any limitation on the amount or type of damages, compensation or benefits payable by or for Contractor or any Subcontractor under the applicable workers’ compensation benefit acts, disability statute or other employee benefit acts.

 

30.4

NOTICE AND DEFENSE.

30.4.1 Subject to the foregoing provisions of this Article 30, within fifteen (15) days of receipt by an indemnified party under this Article 30 of notice of the commencement of any action, such indemnified party will, if a claim in respect thereof is to be made against the indemnifying party under Section 30.1 or Section 30.2 above, provide Notice to the indemnifying party of the commencement thereof. The indemnifying party shall have no liability under this Article 30 for any claim or action for which the indemnified party has admitted any liability or which such Notice is not provided to the extent that such failure to give Notice actually and materially prejudices the indemnifying party’s ability to defend against such claim. In case any such action is brought against any indemnified party and it provides Notice to the indemnifying party of the commencement thereof, the indemnifying party shall assume on behalf of such indemnified party, and conduct with due diligence and in good faith, the defense of any such action against such person, whether or not the indemnifying party is joined therein; provided, however, that, without relieving the indemnifying party of its obligations hereunder, the indemnified party may elect to participate, at its expense, in the defense of any such suit. The indemnifying party shall have the right to assume the defense of any such claim or action with counsel designated by the indemnifying party and reasonably satisfactory to the indemnified party, provided, however, that if the defendants in any such action include both indemnifying party and the indemnified party, and the indemnified party shall have reasonably concluded that there may be legal defenses available to it which are different from or additional to those available to the indemnifying party, the indemnified party shall have the right to select separate counsel to assert such legal defenses and to otherwise participate in the defense of such action on behalf of such indemnified party, the cost of which shall be subject to indemnification under this Article 30. 

30.4.2 Should any indemnified party be entitled to indemnification under this Article 30 and should the indemnifying party fail to assume the defense of such claim or action, the indemnified party may, at the expense of the indemnifying party contest (or, with the prior consent of the indemnifying party, settle) such claim or action. No indemnifying party shall, without the prior written consent of the indemnified party, effect any settlement of any pending or threatened action in respect of which any indemnified party is or could have been a party and indemnity could have been sought hereunder by such indemnified party unless such settlement includes an unconditional release of such indemnified party from all liability on any claims that are the subject matter of such a pending or threatened action.

 

109


Execution Version

 

30.5

REMEDIES NOT EXCLUSIVE.

The rights of indemnity shall not be exclusive with respect to any other right or remedy provided for herein.

 

30.6

TAX EFFECT OF INDEMNIFICATION.

Notwithstanding anything to the contrary contained herein, any indemnity payments owed by a Party shall be reduced by any tax benefits to the indemnified Person and increased by any tax detriments to the indemnified Person resulting from such indemnity payment (including tax detriments resulting from any additional indemnity payments pursuant to the provisions of this Section 30.6), such tax benefits or detriments, if not mutually agreed by the Parties, to be determined by an independent, mutually agreed upon tax consultant.

 

31.

EVENTS OF DEFAULT; REMEDIES.

 

31.1

CONTRACTOR EVENTS OF DEFAULT.

Contractor shall be in default of its obligations under this Agreement if any of the following events arise or exist and is continuing and Contractor shall fail to remedy the same within [***] Days after Owner’s Notice of the occurrence of such event, or if such remedy cannot reasonably be completed in such time, Contractor shall fail promptly to commence and diligently (a) pursue remedial action within such period and (b) conclude such action as soon as practicable (and in any event within [***] Days after the occurrence of such event); provided, however, that (i) no such cure period shall be allowed as to Sections 31.1.1, 31.1.3, 31.1.7 and 31.1.16 and (ii) with respect to Sections 31.1.2, 31.1.6 and 31.1.9 the sole cure period shall be as set forth therein:

31.1.1 Contractor or Contractor Guarantor commences any case, proceeding or other action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of itself or its debts or assets, or adopts an arrangement with or makes an assignment for the benefit of creditors, under any bankruptcy, moratorium, rearrangement, insolvency, reorganization or similar law for the relief of creditors or affecting the rights or remedies of creditors in general or is declared insolvent or Contractor or Contractor Guarantor conceals or removes any part of its property with the intent to hinder, delay or defraud its creditors, or makes or suffers any transfer of its property which may be fraudulent under applicable Law, or admits in writing its inability to pay its debts;

31.1.2 there shall be instituted against Contractor or Contractor Guarantor any case, proceeding or action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of Contractor or Contractor Guarantor or its debts or assets, which shall not have been terminated, stayed or dismissed within [***] Days after commencement, or a trustee, receiver, custodian or other like official is appointed for or to take possession of all or any part of the property or assets of Contractor or Contractor Guarantor, or Contractor or Contractor Guarantor generally does not pay its debts as they become due;

 

110


Execution Version

 

31.1.3 Contractor assigns or transfers this Agreement or any of its rights or interests herein, except as expressly permitted hereunder, or the Contractor Guarantor assigns or transfers the Contractor Guarantee to which it is a party;

31.1.4 Contractor disregards or fails to comply with any Laws, Permit, Applicable Codes and Standards or any instruction regarding Contractor’s performance of the Work given by Owner’s Representative in writing in accordance with this Agreement;

31.1.5 any representation or warranty made by Contractor herein was materially inaccurate or misleading when made;

31.1.6 any Performance Security is not delivered to Owner within [***] Days of when due in accordance with this Agreement, or if delivered to Owner, expires or is terminated or repudiated, and is not replaced by Contractor as required in accordance with the express terms of this Agreement;

31.1.7 an Abandonment of the Project occurs;

31.1.8 Contractor, after a delay in or suspension of the Work permitted by this Agreement, fails or refuses to commence performance of the Work after the cessation of such delay or suspension as provided in Section 17.1;

31.1.9 Contractor fails to pay or cause to be paid any undisputed amount that is due and payable to Owner within [***] days from the date such payment is due;

31.1.10 Contractor fails to maintain in full force and effect insurance policies of such types, in such amounts and with such deductibles, as are required pursuant to this Agreement;

31.1.11 any of the following occurs: (a) Contractor fails to supply sufficient skilled workers or suitable Materials in accordance with the Project Schedule and the Contractor’s manpower charts; or (b) Contractor fails to make prompt, undisputed payments when due to Subcontractors for labor, materials or equipment;

31.1.12 Contractor suspends performance of a material portion of the Work (other than as provided in Section 17.1.1 or Article 33 or pursuant to a Change Order);

31.1.13 Contractor defaults in its observance or performance of any of the terms, conditions and/or restrictions of Article 40;

31.1.14 Contractor fails to make good any Defects, Deficiencies or damage as described in Section 20.5;

31.1.15 Contractor fails to discharge or bond liens filed as required under this Agreement;

31.1.16 Contractor becomes legally domiciled in the State of Louisiana;

31.1.17 Contractor’s liability for any of LPS1 Schedule Delay Liquidated Damages, LPS2 Schedule Delay Liquidated Damages, LPS3 Schedule Delay Liquidated Damages, LPS4 Schedule

 

111


Execution Version

 

Delay Liquidated Damages or Facility Substantial Completion Schedule Delay Liquidated Damages exceeds the LPS1 Schedule Delay Liquidated Damages Cap, LPS2 Schedule Delay Liquidated Damages Cap, LPS3 Schedule Delay Liquidated Damages Cap, LPS4 Schedule Delay Liquidated Damages Cap or Facility Substantial Completion Schedule Delay Liquidated Damages Cap, respectively;

31.1.18 the Contractor Guarantor materially breaches its obligations under the Contractor Guarantee to which it is a party; and

31.1.19 Contractor defaults in its observance or performance of any other material provision hereunder (except defaults for which the payment of liquidated damages is the sole and exclusive remedy as provided in Article 22).

 

31.2

REMEDIES.

31.2.1 In the event that a Contractor default identified in Section 31.1 is continuing following the applicable cure periods described in Section 31.1, Owner shall have any or all of the following rights and remedies, and Contractor shall have the following obligations:

(a) Owner, without prejudice to any of its other rights or remedies under this Agreement, may unilaterally terminate this Agreement immediately by delivery of a Notice of termination to Contractor;

(b) If requested by Owner, Contractor shall withdraw from the Job Site, assign to Owner its rights and obligations under such Subcontracts as Owner may request, and remove such Materials, construction equipment, tools and instruments used by and any debris or waste materials generated by Contractor in the performance of the Work, and Owner, at its sole option, may enter onto the Job Site and take possession of all equipment, tools, supplies, scaffolding and machinery rented by Contractor, any and all designs, remaining Materials (and special tools comprising Materials), Subcontracts, correspondence, schedules, Deliverables and facilities of Contractor that Owner deems necessary to complete of the Work;

(c) Owner, without incurring any liability to Contractor, shall have the right (either with or without the use of the Materials, tools and instruments) to have the Work finished by itself or by another contractor; and

(d) Owner may recover amounts owing to it (as calculated in accordance with Section 31.3 below) by Contractor by enforcing its rights in respect of the Performance Security.

31.2.2 Owner may, without prejudice to any of its other rights or remedies, (a) seek performance by the Contractor Guarantor or any other guarantor of Contractor’s obligations hereunder, (b) seek equitable relief to cause Contractor to take action or to refrain from taking action pursuant to this Agreement, or to make restitution of amounts improperly received under this Agreement, (c) make such payments or perform such obligations as are required to cure such Contractor default, draw on or make a claim against any Performance Security or other security provided pursuant to this Agreement and/or offset the cost of such payment or performance against

 

112


Execution Version

 

payments otherwise due to Contractor under this Agreement; provided that Owner shall be under no obligation to cure any such Contractor default or (d) seek damages as provided in Section 31.3, including proceeding against any bond, letter of credit or guarantee given by or for the benefit of Contractor for its performance under this Agreement.

 

31.3

DAMAGES.

In the event of any termination by Owner of this Agreement pursuant to Section 31.2.1, Contractor shall, subject to Section 21.1, be liable to Owner for the amount of any costs and expenses reasonably incurred by Owner or any Person acting on Owner’s behalf in completing the Work and other expenses and fees related thereto in an attempt to achieve Final Completion by the Final Completion Deadline, or if such date has already passed, at the earliest possible date, less any amounts Owner would have been obligated to pay to Contractor as Total Costs hereunder in respect of completing such Work assuming this Agreement had not been so terminated (collectively, the “Cover Costs”), but only to the extent that (x) the aggregate sum of Cover Costs plus (i) all amounts paid or payable to Contractor under this Agreement prior to termination of this Agreement; plus (ii) amounts or costs paid or incurred by Owner prior to termination of this Agreement that have been included in the calculation of Total Costs pursuant to this Agreement, exceeds (y) the Target Price. See Exhibit B-4 for example calculations of Cover Costs. Owner shall be entitled to withhold further payments to Contractor until Owner determines or it is determined pursuant to the dispute resolution provisions set forth in Article 36 that Contractor is entitled to further payments. Promptly following Final Completion, the calculation of Cover Costs shall be determined by Owner, and Owner shall notify Contractor in writing of the amount, if any, that Contractor shall pay to Owner or Owner shall pay to Contractor, which amount shall be paid within thirty (30) Days of Notice from Owner.

 

31.4

OWNER REMEDIES.

The remedies of Owner set forth herein in respect of Contractor’s obligations and liabilities are in addition to any other remedies that might otherwise be available to Owner at law or in equity.

 

31.5

OWNER DEFAULT.

31.5.1 The following shall constitute a default by Owner:

(a) Subject to the provisions of this Agreement excusing such action, Owner shall fail to pay when due any undisputed amount under this Agreement and such failure shall continue uncorrected for a period for [***] Days after Notice thereof from Contractor;

(b) Owner commences any case, proceeding or other action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of itself or its debts or assets, or adopts an arrangement with or makes an assignment for the benefit of creditors, under any bankruptcy, moratorium, rearrangement, insolvency, reorganization or similar law for the relief of creditors or affecting the rights or remedies of creditors in general or is declared insolvent or Owner conceals or removes any part of its property with the intent to hinder, delay or defraud its creditors, or makes or suffers any transfer of its property which may be fraudulent under applicable Law, or admits in writing its inability to pay its debts; and

 

113


Execution Version

 

(c) There has been instituted against Owner any case, proceeding or action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of Owner or its debts or assets, which shall not have been terminated, stayed or dismissed within [***] Days after commencement, or a trustee, receiver, custodian or other like official is appointed for or to take possession of all or any part of the property or assets of Owner, or Owner generally does not pay its debts as they become due; provided, however, that Owner shall have [***] Days to cure this default following Notice thereof from Contractor.

31.5.2 Contractor shall have the right to terminate this Agreement upon the occurrence of a default by Owner by delivery of a Notice of termination to Owner. Upon such termination, Contractor will be compensated (i) the Reimbursable Costs, Contractor’s G&A and Contractor’s Margin for all Work performed through the date of termination, and (ii) the reasonable costs to demobilize and any unavoidable cancellation charges from Subcontractors. Any such termination shall not relieve Contractor of its obligations to perform Corrective Work during any applicable Warranty Period.

 

31.6

OBLIGATIONS UPON TERMINATION.

31.6.1 Any termination of this Agreement (whether by Owner or Contractor) shall not relieve (a) Contractor and Owner of each of its obligations with respect to confidentiality as set forth herein, (b) any Party of any obligation hereunder which expressly or by implication survives termination hereof, (c) Owner of its obligation to pay amounts owing to Contractor pursuant to Section 31.5.2 and (d) any Party of its indemnity obligations or liabilities for loss or damage to another Party in accordance with this Agreement, and shall not relieve Contractor of its obligations and liabilities for the portions of the Work already completed prior to the date of termination.

31.6.2 Upon a termination of this Agreement pursuant to this Article 31 or Article 32: (a) Contractor shall leave the Job Site and remove from the Job Site all Contractor equipment, waste, rubbish and Hazardous Substances as Owner may request; (b) Owner shall take possession of the Job Site and of the Materials (whether at the Job Site, in transit or otherwise); (c) except as otherwise directed by Owner, Contractor shall promptly assign to Owner or its designee any contract rights (including warranties, licenses, patents and copyrights) that it, or any of its Subcontractors, has to any and all Materials, Deliverables and the Work, including contracts with Subcontractors and Contractor shall execute such documents as may be reasonably requested by Owner to evidence such assignment, subject to Owner’s assumption of same and, if required, Owner’s adequate assurance to such Subcontractors regarding Owner’s ability to pay; (d) to the extent so directed by the Owner, Contractor shall cancel as quickly as possible and upon terms satisfactory to Owner all orders placed by it with Subcontractors and shall use all reasonable efforts to minimize cancellation charges and other costs and expenses associated with the termination of this Agreement unless Owner elects to take assignment of any such Subcontracts; (e) Contractor shall cooperate with Owner for the efficient transition of the Work and thereafter shall use commercially reasonable efforts to execute that portion of the Work as may be necessary to preserve and protect Work already in progress and to protect Materials at the Job Site or in transit

 

114


Execution Version

 

thereto, and to comply with any applicable Law, Permits and any Applicable Codes and Standards; (f) Contractor shall promptly furnish Owner with copies of all Deliverables, Auto CAD compatible electronic files, Drawings and Specifications and, to the extent available, final “as-built” drawings, in compliance with Exhibit J; (g) Contractor shall provide Owner and its designee with the right to use, free of charge, all other patented, copyrighted and other proprietary information or Intellectual Property relating to the Work that Owner deems necessary to complete the Work, and Contractor shall execute such documents as may be reasonably requested by Owner to evidence such right; (h) Contractor shall assist Owner in preparing an inventory of all Materials in use or in storage at the Job Site; and (i) Contractor shall take such other action as required hereunder upon termination of this Agreement. In the event that Contractor terminates this Agreement pursuant to and in accordance with Section 31.5.2, Contractor shall not be obligated to comply with paragraphs (c) through (h) (inclusive) of this Section 31.6.2(b) unless and until a Lender or another Person on behalf of Owner has cured, or has agreed in writing to cure, Owner’s default.

 

32.

TERMINATION FOR CONVENIENCE.

 

32.1

GENERAL.

32.1.1 Owner may in its sole discretion terminate the Work without cause at any time by giving Notice of termination to Contractor and such termination shall be effective upon the giving of such notice by Owner. If the Work is terminated by Owner without cause, Owner and Contractor shall have the following rights, obligations and duties:

(a) upon receiving any Notice of termination, Contractor shall stop performing the Work and, except for Subcontracts that Owner elects to take assignment of or as otherwise directed by Owner, shall cancel as quickly as possible all orders placed by it with Subcontractors and shall use all reasonable efforts to minimize cancellation charges and other costs and expenses associated with the termination of this Agreement;

(b) if Owner terminates the Work pursuant to this Section 32.1 after the issuance of a Limited Notice to Proceed, Contractor will be compensated for the Work performed under such Limited Notice to Proceed through the date of termination, plus reasonable costs to demobilize and any unavoidable and reasonable cancellation charges from Subcontractors under Subcontracts not assumed pursuant to Section 32.1.1(c); provided, however, that the amount payable for the Work actually completed by Contractor shall be subject to adjustment to the extent the Work requires Corrective Work;

(c) following a termination by Owner pursuant to this Section 32.1, Owner shall have the right, at its option, to assume and become liable for any reasonable written obligations and commitments that Contractor may have in good faith undertaken with third parties in connection with the Work, which obligations and commitments are not covered by the payments made to Contractor under Section 32.1.1(b). If Owner elects to assume any obligation of Contractor as described in this Section 32.1.1(c), then, as a condition precedent to Owner’s compliance with any section of this Article 32, Contractor shall execute all papers and take all other reasonable steps requested by Owner which may be required to vest in Owner all rights, set-offs, benefits and titles necessary to such assumption by Owner of such obligations described in this Article 32; and

 

115


Execution Version

 

32.1.2 Notwithstanding anything to the contrary contained herein, in the event Owner terminates this Agreement pursuant to this Article 32 for any reason prior to the issuance of a Limited Notice to Proceed or, if no Limited Notice to Proceed is issued, prior to the issuance of the Notice to Proceed, Contractor shall not be entitled to any remuneration from Owner.

 

32.2

CLAIMS FOR PAYMENT FOLLOWING TERMINATION FOR CONVENIENCE.

Any claim for payment by Contractor under this Article 32 must be made within sixty (60) Days after the effective date of a termination hereunder, and Owner’s payment thereof shall be made pursuant to the payment protocol set forth in Article 6.

 

33.

FORCE MAJEURE.

 

33.1

EXTENSION OF TIME FOR FORCE MAJEURE EVENT.

An equitable adjustment of the Target Price or any component thereof and of scheduled and guaranteed dates shall be granted to Contractor pursuant to a Change Order for a Force Majeure Event.

 

33.2

CONTRACTOR’S RESPONSIBILITY.

33.2.1 Contractor shall work diligently to cure, remove, otherwise correct, minimize and contain all costs and expenses attendant on or arising from each Force Majeure Event including expenditures for avoidance or reduction of the effect of a Force Majeure Event. The failure of Contractor to perform such Work shall be reason for denial of the full extension of time, which would otherwise be justified. The extension of time for a Force Majeure Event shall be that duration of time jointly and reasonably determined by Owner, the Independent Engineer and Contractor to be reasonably necessary to make up the aggregate amount of time actually lost across all affected activities, all pursuant to the Change Order provisions of Article 12.

33.2.2 Contractor shall provide Notice of any Force Majeure Event to Owner and the Independent Engineer upon obtaining actual knowledge of the occurrence of such Force Majeure Event pursuant to and in accordance with Section 12.2.1.

 

33.3

CONTINUING RESPONSIBILITY OF CONTRACTOR.

If a Force Majeure Event occurs, Contractor shall remain responsible for completing the Work in accordance with the Project Schedule as adjusted pursuant to a Change Order.

 

33.4

PERFORMANCE NOT EXCUSED.

The payment of money owed shall not be excused because of a Force Majeure Event or Owner Caused Delay. In addition, neither Owner nor Contractor shall be excused under this Article 33 from timely performance of their obligations hereunder to the extent that a claimed Force Majeure Event was caused by any negligent or intentional acts, errors or omissions, willful misconduct or for any breach or default of this Agreement by such Party. Furthermore, no suspension of performance or extension of time shall relieve the Party benefiting therefrom from any liability for any breach of the obligations that were suspended or failure to comply with the

 

116


Execution Version

 

time period that was extended to the extent such breach or failure occurred prior to the occurrence of the applicable Force Majeure Event or Owner Caused Delay. Notwithstanding anything to the contrary contained herein, Contractor shall not be entitled to any adjustment to the Target Price in respect of demobilization and/or remobilization required as a result of any Force Majeure Event.

 

34.

DUTIES AND TAXES.

 

34.1

ALLOCATION OF RESPONSIBILITIES.

Contractor shall pay and administer, as Direct Costs, any and all Taxes payable in connection with the Work including, but not limited to Taxes imposed on services and Contractor’s purchase or rental of equipment, tools, and supplies used by Contractor in the performance of the Work, or the Materials incorporated into, installed in, or affixed or attached to the Facility (collectively “Contractor Taxes”); provided, however that any Taxes based on or related to the net income, capital or net worth of Contractor or any Subcontractor shall be Non-Reimbursable Costs. Notwithstanding anything in the Agreement to the contrary, Owner shall be solely responsible for and shall, as required by applicable Law, pay the appropriate Government Authority all property taxes and other Taxes directly associated with: (i) its ownership and operation and maintenance of the Job Site, the Facility, and any Materials to be installed in, incorporated into, or affixed or attached to the Facility, and (ii) the supply of the Owner Furnished Equipment and Materials and performance of the Owner Scope of Work. Contractor shall reasonably cooperate with Owner to minimize any Taxes payable by Owner hereunder. If applicable, Owner shall timely provide Contractor: (i) a schedule identifying any portion of the Work eligible for exemption from Taxes; and (ii) a valid exemption certificate or any other documentation required by applicable Laws, demonstrating Owner’s eligibility for such exemption. Owner shall indemnify, defend, and hold Contractor harmless from and against all Taxes: (i) arising from disallowance of any exemption asserted by Owner under the Agreement; or (ii) Owner’s failure to comply with its Tax obligations under the Agreement.

 

34.2

LOUISIANA TAX AND INCENTIVES PROVISIONS.

Pursuant to state Law, certain tax and incentive programs are available to qualifying manufacturers in certain circumstances, including the Louisiana Quality Jobs Program, Enterprise Zone Program, and the Manufacturing Machinery and Equipment sales tax exclusion. Owner has not determined which, if any, of these programs it will pursue. Contractor shall reasonably cooperate with and assist Owner and any designated tax and incentive consultant, and shall require Subcontractors to reasonably cooperate with and assist Owner and any designated tax and incentive consultant, in obtaining tax and incentive benefits under these and any other available programs. Such assistance may include, but is not limited to, documenting purchase transactions, providing reports and supporting documents required to be submitted to obtain the tax and incentive benefits, and acting as agent for Owner in connection with the purchase of manufacturing machinery and equipment.

 

117


Execution Version

 

35.

BINDING AGREEMENT; ASSIGNMENT.

 

35.1

BY OWNER.

The terms of this Agreement shall be binding upon Owner and its successors and assigns. Without the prior consent of Contractor, Owner may, upon prior written Notice to Contractor, assign all or part of Owner’s right, title and interest herein to any Lenders, any Affiliate of Owner, any successor to Owner’s business (whether by merger, acquisition or otherwise) or to any financially responsible assignee that agrees to be bound by the terms hereof. In addition, Owner may assign all or part of its right, title and interest herein to any other Person with the prior written approval of Contractor, which approval shall not be withheld unreasonably. Contractor acknowledges that the Lenders may under certain circumstances foreclose upon and sell, or cause Owner to sell or lease the Facility and cause any new lessee or purchaser of the Facility to assume all of the interests, rights and obligations of Owner arising under this Agreement. In such event, Contractor agrees to the assignment by Owner and the Lenders of this Agreement and its rights herein to such purchaser or lessee and shall release Owner and the Lenders from all obligations hereunder upon any such assignment, provided that such new lessee or purchaser assumes Owner’s obligations under this Agreement.

 

35.2

BY CONTRACTOR.

The terms of this Agreement shall be binding upon Contractor and its successors and permitted assigns, provided that assignment by Contractor of this Agreement or any partial or total interest therein without Owner’s and the Lenders’ prior written consent (at their sole and unfettered discretion) shall be null and void.

 

36.

DISPUTES.

 

36.1

DISPUTE RESOLUTION.

36.1.1 Any dispute, controversy or claim between the Owner and Contractor that arises out of, under or in connection with this Agreement, including its interpretation, performance, enforcement, termination, validity or breach (each a “Dispute”) shall be subject to resolution under this Article 36, which shall be the exclusive dispute resolution method for any such Dispute. If Owner or Contractor wish to declare a Dispute they shall deliver to the other Party a written notice identifying the disputed issue (a “Notice of Dispute”).

36.1.2 Following the delivery of a Notice of Dispute, the Parties will attempt in good faith to resolve such Dispute promptly through negotiation. If the Dispute has not been resolved within thirty (30) days after the date on which the Notice of Dispute was delivered, then any Party shall be permitted to submit such Dispute to binding arbitration in accordance with Section 36.1.3.

36.1.3 Any Dispute that is not resolved pursuant to Section 36.1.2 shall be exclusively and definitively resolved through final and binding arbitration conducted in accordance with the Rules of Arbitration of the ICC, which (save as modified by this Section 36.1.3) are deemed to be incorporated by reference into this Section 36.1.3.

 

118


Execution Version

 

(a) The arbitration tribunal shall consist of three (3) arbitrators. One (1) arbitrator shall be appointed by Owner, one (1) arbitrator shall be appointed by Contractor, and the third arbitrator shall be selected by agreement of the first two (2) arbitrators. If either of the first two (2) appointments is not made within thirty (30) Days after the request for arbitration, or if the first two (2) arbitrators fail to agree on a third arbitrator within thirty (30) Days after the later of them has been appointed, the unfilled appointment will be made, at the request of either Owner or Contractor, by the ICC. No arbitrator appointed pursuant to this Section 36.1.3(a) shall be an employee, agent, competitor or former employee, agent or contractor of, or have or have had any material interest (directly or indirectly) in the business of or in any Party or any of its Affiliates. Each arbitrator shall be knowledgeable with respect to engineering, procurement and construction contracts and shall be fluent in the English language.

(b) Unless the Parties agree in writing otherwise:

(1) the seat of arbitration shall be New York, New York, and the language to be used in the proceedings shall be English;

(2) the arbitrators shall, by majority vote, render a written award stating the reasons for their award within three (3) months after any hearing conducted has been concluded. The arbitral award may contain such orders (including orders for specific performance, setoff, other equitable relief or monetary damages) in respect of or affecting any of the Parties (and/or any Loss suffered by any of them), as such arbitral tribunal determines to be appropriate in the circumstances; provided that the arbitral tribunal shall not have the authority to award any indirect, consequential or punitive damages unless, but only to the extent, such damages are expressly permitted hereunder;

(3) the Parties and the arbitral tribunal will ensure that the arbitration proceedings and any documents disclosed in such proceedings are kept strictly confidential;

(4) the Parties may make an application to any court of competent jurisdiction for the obtaining of any evidence from third parties that the arbitrators direct may be relevant to the arbitral proceedings; and

(5) the responsibility for the costs of the arbitration will be determined by the arbitral tribunal.

(c) An arbitral award rendered in accordance with this Section 36.1.3 shall be final and binding on the Parties. The Parties agree that any arbitral award made pursuant to this Section 36.1.3 may be enforced against the Parties or their assets wherever they may be found and that a judgment upon the arbitral award may be entered (and any other applicable relief, including interlocutory relief, may be granted) in any court having jurisdiction on such matters, and subject to their respective obligations contained elsewhere herein, shall take all such actions as are necessary to give full and complete effect to the award which, in accordance with its terms, shall be binding upon and enforceable against them.

 

119


Execution Version

 

(d) No Party shall be entitled to suspend its performance under this Agreement during the pendency of any Dispute subject to this Section 36.1.3 or during the period during which any defaulting Party is attempting to remedy its non-performance of this Agreement within the periods prescribed therefor in Article 31.

(e) Nothing contained in this Article 36 shall be construed to prohibit any Party from making an application to any court of competent jurisdiction for an order of specific performance or for other injunctive or equitable relief as long as the arbitral tribunal contemplated in this Section 36.1.3 has not yet been formed.

36.1.4 Unless the Parties otherwise agree, no dispute, controversy or claim hereunder shall be consolidated with any other arbitration proceeding involving any third party.

 

36.2

CONTINUATION OF WORK DURING DISPUTE.

Notwithstanding any Dispute, it shall be the responsibility of Contractor to continue to prosecute all of the Work diligently and in a good and workmanlike manner in conformity with this Agreement. Except to the extent provided in Section 31.5.2, Contractor shall have no right to cease performance hereunder or to permit the prosecution of the Work to be delayed. Owner shall, subject to its right to withhold or offset amounts pursuant to this Agreement, continue to pay Contractor undisputed amounts in accordance with this Agreement; provided, however, in no event shall the occurrence of any negotiation or arbitration prevent or affect Owner from exercising its rights under this Agreement, including Owner’s right to terminate pursuant to Sections 31.2 and 32.1.1.

 

37.

INDEPENDENT CONTRACTOR.

 

37.1

GENERAL.

Contractor is an independent contractor and nothing contained herein (including Section 24.5) shall be construed as constituting any relationship with Owner other than that of owner and independent Contractor, nor shall it be construed as creating any relationship whatsoever between Owner and the Contractor’s employees. Neither Contractor nor any of its employees is or shall be deemed to be employees of Owner. Contractor shall not have the authority to act on behalf of Owner or to bind Owner in any manner, except as expressly set forth herein.

 

37.2

EMPLOYEES.

Subject to Section 5.2 and Article 24 hereof, Contractor has sole authority and responsibility to employ, discharge and otherwise control its employees.

 

37.3

RESPONSIBILITY FOR SUBCONTRACTORS, ETC.

Contractor accepts complete responsibility for the acts of its agents, employees, Subcontractors and all others it hires to perform or assist in the performance of the Work. 

 

120


Execution Version

 

38.

NOTICES AND COMMUNICATIONS.

 

38.1

REQUIREMENTS.

38.1.1 Any Notice, request, proposal for changes, Change Order, and correspondence (including drawings, lists, schedules, instruction books, or statements) required or permitted under the terms and conditions of this Agreement shall be in writing and (a) delivered personally, (b) sent by e-mail with the receiving Party retaining a confirmation receipt (and confirming receipt thereof to sender with respect to non-routine materials), (c) sent by a recognized overnight mail or courier service, with delivery receipt requested (with respect to non-routine materials) or (d) sent by mail (return receipt requested with respect to non-routine materials), to the following addresses (or to such other address that the receiving Party may designate from time to time in accordance with this Article 38); provided, however, Requests for Payment (excluding lien waivers) need only be sent as PDF documents by e-mail in the manner described in sub-section (b):

If to Contractor:

If to Owner:

 

121


Execution Version

 

38.1.2 Promptly after the occurrence of the Financial Closing Date, Owner shall provide to Contractor the details for the delivery of Notices under this Agreement to the Independent Engineer and the representative(s) for the Lenders.

 

38.2

EFFECTIVE TIME.

A Notice delivered in accordance with Section 38.1 shall be deemed to have been delivered upon the receipt thereof.

 

38.3

TECHNICAL COMMUNICATIONS.

Any technical or other communications pertaining to the Work shall be between the Contractor’s Representative and Owner’s Representative or other representatives appointed by the Parties. Each Party shall give Notice to the other of the name of such representative or representatives. The Contractor’s Representative shall be satisfactory to Owner, have knowledge of the Work and be available at all reasonable times for consultation. 

 

39.

FINANCING MATTERS.

Owner contemplates obtaining financing (including any refinancing thereof) for the Facility consisting of one or more construction or permanent loans to be secured by all or a portion of the Facility and its rights under this Agreement and certain equity contributions (the “Financing”). In the event Owner applies for or obtains any Financing, Contractor shall, notwithstanding the existence of any Dispute between the Owner and Contractor, promptly execute or consent to a Consent and Agreement in the form attached hereto as Exhibit F-5 (the “Consent and Agreement”), including any additional terms or provisions reasonably requested by any of the Lenders, an Indemnity Undertaking in favor of the title insurance providers in the form attached hereto as Exhibit F-14 from each of Contractor and the Contractor Guarantor, and such other documents, which are reasonably required by the Lenders in connection with such Financing and which are in form and substance reasonably acceptable to the Parties (collectively, the “Financing Deliverables”); provided, however, that Contractor shall have a reasonable period of time prior to the execution of each Financing Deliverable within which to review any such documents. So long as the Lenders’ requested terms or provisions do not materially change or impact the terms of this Agreement, they shall be deemed reasonable. Contractor shall respond to reasonable requests by the Lenders for certificates and legal opinions as well as information regarding the qualifications, experience, past performance and financial condition of Contractor and other matters pertaining to Contractor’s participation hereunder and in the Facility. Contractor’s obligations under this Article 39 shall extend until at least the end of the Warranty Period.

 

40.

COMPLIANCE WITH LAWS.

 

40.1

ANTI-CORRUPTION.

40.1.1 Contractor represents, warrants and covenants that neither it, nor any of its Affiliates (or any of their respective principals, partners or funding sources), is currently (a) a

 

122


Execution Version

 

Person designated by the U.S. Department of Treasury’s Office of Foreign Assets Control as a “specially designated national or blocked person” (“SDN”) or similar status, (b) a person otherwise identified by a government or legal authority as a person with whom Owner is prohibited from transacting business, (c) directly or indirectly owned or controlled by an SDN or the government of any country that is subject to an embargo by the government of the United States of America or (d) a Person acting on behalf of an SDN or a government of any country that is subject to an embargo by the government of the United States of America. Contractor agrees that it will notify Owner in writing immediately upon the occurrence of any event that subsequently results in any of the designations set forth in this Section 40.1.1.

40.1.2 Each Party shall, in the performance of this Agreement, comply with all laws, orders, directives, and regulations in effect on the Effective Date and as they may be amended from time to time that are applicable to the Party. Notwithstanding anything to the contrary contained herein, this Agreement shall not be interpreted or applied so as to require a Party to do, or to refrain from doing, anything that would constitute a violation of federal or state laws and regulations applicable to it, including the Foreign Corrupt Practices Act of 1977, 15 U.S.C. § 78dd-2, the OECD Anti-Bribery Convention, the U.K. Bribery Act of 2010, E.U. and E.U. member country anti-bribery and corruption laws, laws or regulations restricting participation in or compliance with certain foreign boycotts, directly or indirectly, as contained in the U.S. Export Administration Act of 1979, the U.S. Internal Revenue Code or any similar statute, regulation, order or convention binding on the Party, as each may be amended from time to time, and including implementing regulations promulgated pursuant thereto (collectively, the “Anti-Corruption Laws”). Without limiting the foregoing, each Party agrees on behalf of itself, its Affiliates and their respective directors, officers, employees, agents and contractors, not to pay any fees, commissions or rebates to any employee, officer or agent of the other Party or its Affiliates or their respective shareholders, or provide or cause to be provided to any of them any gifts or entertainment of significant cost or value in connection with this Agreement or in order to influence or induce any actions or inactions in connection with the commercial activities of the Parties in connection with this Agreement. Each Party further agrees to cooperate and conduct its business and activities pursuant to this Agreement in such a manner to ensure that no Party or any of their respective Affiliates is placed in a position of non-compliance with federal and state laws and regulations applicable to it, including any reporting requirements.

40.1.3 Contractor represents, warrants and covenants with respect to itself and its Affiliates that, except as disclosed by the Contractor Guarantor in public filings with the U.S. Securities and Exchange Commission (a) it and its Affiliates are being and have been operated in compliance in all material respects with the Anti-Corruption Laws, (b) neither it nor any of its Affiliates has received any written notice or claim alleging any material violation under any of the Anti-Corruption Laws, and (c) neither it nor any of its Affiliates, nor any of their respective directors, officers, or employees (or, to the best of Contractor’s knowledge and belief, any partner, intermediary or other Person acting or purporting to act on behalf of such party or any of its Affiliates) has knowingly directly or indirectly paid, offered, given, promised to pay or authorized the payment of any money or anything of value to (i) any candidate for public office, any past or present employee, director, officer, official, representative or agent of any government, government or legal authority, instrumentality, or any public international organization (“Government Official”), (ii) any Person acting for or on behalf of any Government Official, or (iii) any other Person at the suggestion, request, direction or for the benefit of any of the above- described Persons to obtain, retain or direct business or to obtain special concessions or pay for favorable treatment for business secured or for special concessions already obtained.

 

123


Execution Version

 

40.1.4 Neither Contractor nor any of its Affiliates, directors, officers, employees or agents, shall use its relationship with Owner to attempt to disguise the sources of illegally-obtained funds. Contractor further represents and warrants that no such attempt of the sort described in this Section 40.1.4 has been made prior to the Effective Date.

 

40.2

RECORDS.

Contractor shall keep all records necessary to confirm compliance with Sections 40.1.1 through 40.1.4 for a period of five (5) years following the year for which such records apply. If Owner asserts that Contractor is not in compliance with Section 40.1.1, Section 40.1.2, Section 40.1.3 or Section 40.1.4, Owner shall send Notice to Contractor indicating the type of non-compliance asserted. After giving such Notice, Owner may cause an independent auditor to audit the records of Contractor in respect of the asserted non-compliance. The costs of any independent auditor under this Section 40.2 shall be paid (a) by Contractor, if Contractor is determined not to be in compliance with Section 40.1.1, Section 40.1.2, Section 40.1.3 or Section 40.1.4 or (b) by Owner, if Contractor is determined to be in compliance with Section 40.1.1, Section 40.1.2, Section 40.1.3 and Section 40.1.4.

 

40.3

EXPORT CONTROLS.

40.3.1 The Parties agree to comply with all applicable United States (“U.S.) and non-U.S. export control and economic sanctions laws in the performance of this Agreement, including any restrictions or conditions regarding the export, re-export, or other transfer of the Deliverables that are in effect now or are hereafter imposed by the U.S. or other Government Authority. Each Party shall be responsible for its own compliance with applicable export control and economic sanctions laws with regards to their Affiliates, employees, facilities and activities. These restrictions and conditions include (a) restrictions and export licensing requirements governing the export, re-export, or other transfer to other persons, entities, or countries of the Deliverables, (b) restrictions and export licensing requirements governing the export or other transfer of foreign-developed information that incorporates the Deliverables, (c) any applicable U.S. and other restrictions on the export, re-export, or other transfer of the Deliverables to countries, entities and persons that are subject to U.S. or other applicable sanctions, embargoes, or other prohibitions and (d) any applicable U.S. or other restrictions on the export or other transfer of the direct product of U.S. or other origin technical data (collectively, the “Export Controls”). Contractor shall provide Owner written Notice prior to transferring any Deliverable, commodity, software or technology that is: (i) controlled at a level greater than EAR99 under the Export Administration Regulations (“EAR”); or (ii) subject to the jurisdiction of an export control regime other than the EAR.

40.3.2 Each Party acknowledges that the other Party would not have an adequate remedy at law for money damages if the covenants contained in this Section 40.3 were breached and that any such breach would cause the other Party irreparable harm. Accordingly, each Party agrees that, in the event of any breach or threatened breach of the terms of this Section 40.3 by such Party, the other Party, in addition to any other remedies that it may have, shall be entitled, individually or jointly, without the requirement of posting a bond or other security, to equitable relief, including injunctive relief and specific performance.

 

124


Execution Version

 

40.4

SUBCONTRACTORS; INDEMNIFICATION.

40.4.1 Contractor agrees that with regard to any activities conducted pursuant to this Agreement, it will require its Subcontractors to agree to and comply with contractual provisions substantially equivalent to those contained in this Article 40.

40.4.2 Contractor agrees to indemnify and hold Owner, the Owner’s Affiliates and their respective shareholders, directors, officers, employees, agents, consultants or representatives harmless from any claims by Government Authorities for fines and penalties arising out of Contractor’s violation of Anti-Corruption Laws or Export Controls.

 

41.

MISCELLANEOUS.

 

41.1

FURTHER ASSURANCES AND EXPENSES.

The Parties undertake to act fairly and in good faith and use their reasonable efforts in relation to the performance and implementation of this Agreement and to take such other reasonable measures as may be necessary for the realization of its purposes and objectives, including, at the request of another Party, without further consideration, promptly executing and delivering or causing to be executed and delivered to such Party such assistance, or consents or other instruments in addition to those required by this Agreement, in form and substance satisfactory to such Party, as such Party may reasonably deem necessary or desirable to implement anything contained herein. Each Party shall pay its own costs and expenses in relation to the negotiation, preparation, execution and carrying into effect of this Agreement (including in connection with the preparation and negotiation of amendments and Change Orders), which, in the case of Contractor, constitute Non-Reimbursable Costs hereunder.

 

41.2

RECORD RETENTION.

Contractor agrees to retain for a period of five (5) years from the date of Final Completion all records relating to its performance of the Work, and to cause all Subcontractors engaged in connection with the Work to retain for the same period all their records relating to the Work.

 

41.3

NO WAIVER.

No waiver of any of the terms and conditions of this Agreement shall be effective unless in writing and signed by the Party against whom such waiver is sought to be enforced. Any waiver of the terms hereof shall be effective only in the specific instance and for the specific purpose given. The failure of a Party to insist, in any instance, on the performance of any of the terms and conditions hereof shall not be construed as a waiver of such Party’s right in the future to insist on such performance.

 

125


Execution Version

 

41.4

SEVERABILITY.

The invalidity or unenforceability, in whole or in part, of any portion or provision of this Agreement will not affect the validity or enforceability of any other portion or provision hereof. Any invalid or unenforceable portion or provision shall be deemed severed from this Agreement and the balance of this Agreement shall be construed and enforced as if this Agreement did not contain such invalid or unenforceable portion or provision; provided, however, the Parties agree to negotiate in good faith to replace the invalid or unenforceable provision with a valid and enforceable provision that will, to the extent possible, preserve the intended economic positions of the Parties.

 

41.5

BINDING ON SUCCESSORS.

This Agreement shall be binding on the Parties hereto and on their respective successors, heirs and permitted assigns.

 

41.6

GOVERNING LAW.

41.6.1 THIS AGREEMENT SHALL IN ALL RESPECTS BE GOVERNED BY, AND CONSTRUED IN ACCORDANCE WITH THE LAW OF THE STATE OF NEW YORK WITHOUT REGARD TO PRINCIPLES OF CONFLICTS OF LAWS. Each of the Parties hereby submits to the non-exclusive jurisdiction of the federal courts or state of New York courts with venue in the State of New York for the purposes of all legal proceedings arising out of or relating to this Agreement or the transactions contemplated hereby. Each of the Parties irrevocably waives, to the fullest extent permitted by applicable Law, any objection that it may now or hereafter have to the laying of the venue of any such proceeding brought in such a court and any claim that any such proceeding brought in such a court has been brought in an inconvenient forum. The Parties agree that a judgment in any suit, action or proceeding in such a court shall be conclusive and may be enforced in other jurisdictions by suit on the judgment or by any other manner provided by law, and each of the Parties waives any defense or objection they may have regarding the validity or enforceability of any such judgment; provided, however, that such judgment shall not constitute a waiver of any rights of appeal. Nothing in this Section 41.6 shall be deemed to modify the provisions of Article 36.

41.6.2 EACH OF THE PARTIES HEREBY IRREVOCABLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY AND ALL RIGHT TO TRIAL BY JURY IN ANY LEGAL PROCEEDING ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY.

 

41.7

SET-OFF.

Notwithstanding anything to the contrary contained herein, any and all amounts owing or to be paid by Owner to Contractor hereunder, shall be subject to offset and reduction in an amount equal to any amounts that may be owing at any time by Contractor to Owner hereunder. Further, for the avoidance of doubt, with respect to anything contained herein that allows Owner to offset, set-off or draw against any Performance Security any amount then owed to Contractor, Owner shall have the express right to include in the amount offset, set-off or drawn under such Performance Security all of the reasonable costs and expenses it incurs in connection with enforcing such provision (including reasonable attorneys’ and other consultants’ fees).

 

126


Execution Version

 

41.8

AMENDMENT.

No amendment, modification or supplement of or to this Agreement shall be binding and effective unless in writing and signed by all of the Parties.

 

41.9

HEADINGS FOR CONVENIENCE ONLY.

The headings of the various sections contained herein are not part of this Agreement and are included solely for convenience of the Parties.

 

41.10

NONDISCRIMINATION.

Contractor agrees that in the performance of the Work under this Agreement, it will not knowingly violate any applicable Laws prohibiting discrimination in employment.

 

41.11

COUNTERPART EXECUTION.

This Agreement may be executed by the Parties in any number of counterparts (and by each of the Parties on separate counterparts), each of which when so executed and delivered shall be an original, but all such counterparts shall together constitute but one and the same instrument. The .pdf or electronic signatures of the Parties shall be deemed original signatures, and .pdf or electronic copies hereof shall be deemed to constitute duplicate originals.

 

41.12

THIRD-PARTY BENEFICIARIES.

Except with respect to the rights of successors and permitted assigns as provided herein, any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders) and the rights of indemnitees under Article 30, (a) nothing contained herein nor any action taken hereunder shall be construed to create any duty, liability or standard of care to any Person that is not a Party, (b) no person that is not a Party shall have any rights or interest, direct or indirect, in this Agreement or the services to be provided hereunder and (c) this Agreement is intended solely for the benefit of the Parties, and the Parties expressly disclaim any intent to create any rights in any third party as a third-party beneficiary to this Agreement or the services to be provided hereunder.

 

41.13

SURVIVAL OF OBLIGATIONS.

Notwithstanding anything to the contrary contained herein, any termination of this Agreement shall not relieve (a) any Party of its obligations with respect to confidentiality as set forth herein, (b) any Party of any obligation hereunder which expressly or by implication survives termination hereof (including the provisions of Articles 17, 21, 24, 29, 30, 36 and 41 and Section 6.4) and (c) any Party of its obligations or liabilities for loss or damage to another Party arising out of or caused by acts or omissions of such first Party prior to the effectiveness of such termination or arising out of such termination, and shall not relieve Contractor of its obligations and liabilities for the portions of the Work already performed prior to the date of termination.

 

127


Execution Version

 

41.14

ENTIRE AGREEMENT.

This Agreement embodies the entire agreement among the Parties relating to the specific subject matter hereof and supersedes all prior written agreements regarding the subject matter hereof. The Parties shall not be bound by or liable for any documents proposed or submitted prior to the Effective Date and not incorporated into (by reference or otherwise) or referred to in this Agreement, or by or for any statement, representation, promise, inducement or understanding of any kind or nature relating to the Work or any other matter covered by this Agreement which is not set forth or provided for herein. All waivers, releases, exclusions of and limitations on liability and remedies expressly stated herein shall apply to the Parties and their respective Affiliates and employees, regardless of whether arising in contract, warranty, tort (including negligence), statutory or strict liability or otherwise.

 

41.15

RELATIONSHIP.

Nothing contained herein shall be deemed to constitute, create, give effect to, constitute any commitment to, or otherwise recognize or contemplate a joint venture, partnership or formal business entity of any kind, and the rights and obligations of the Parties shall be expressly limited only to those expressly set forth herein. Except as provided in Exhibit Z, there shall be no other or implied obligations hereunder, including any obligation or commitment in respect of the second phase of CP2 LNG (excluding LPS4) having a nameplate capacity of five decimal six (5.6) MTPA.

 

41.16

LIMITED RECOURSE.

The Parties’ sole recourse for any damages or liabilities due pursuant to this Agreement shall be limited to the remedies provided under the Contractor Guarantee, the Performance Security and the assets of the other Party and, except as provided in the Contractor Guarantee, without recourse individually or collectively to the assets of the members or the Affiliates of any other Party, the Lenders or their respective directors, agents, members, shareholders, managers, employees, representatives, partners and officers.

[Signatures appear on the following page]

 

128


Execution Version

 

IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed by their duly authorized representatives as of the Effective Date.

 

VENTURE GLOBAL CP2 LNG, LLC

 

By: /s/ Jonathan Thayer            
Name: Jonathan Thayer

Title: Chief Financial Officer

 

WORLEY FIELD SERVICES INC.
By: /s/ Mark Trueman             
Name: Mark Trueman
Title: Group President, Americas

 

 

 

[EPC Agreement Signature Page]


Execution Version

 

EXHIBIT A

SCOPE OF WORK; APPLICABLE CODES AND STANDARDS

[Omitted]

 

1


Execution Version

 

EXHIBIT B

COMPENSATION

[Omitted]

 

1


Execution Version

 

EXHIBIT B-1

DIRECT COSTS AND NON-REIMBURSABLE COSTS

 

1.

Direct Costs.

 

  1.1

Direct Costs are comprised of Direct Labor Costs and Other Direct Costs.

 

  1.1.1

Direct Labor Costs” means the Non-Craft Direct Labor Costs and the Craft Direct Labor Costs, in each case, incurred by Contractor with respect to the performance of the Reimbursable Work, excluding in all cases any Non-Reimbursable Costs.

 

  (a)

Non-Craft Direct Labor Costs” or “Staff” as used herein means, with respect to each category of Contractor’s non-craft employees identified in Exhibit C and the Personnel Authorization Assignment Form (PAAF), (i) the actual, verifiable and documented hours worked by such Contractor non-craft employees in the performance of the Reimbursable Work multiplied by (ii) the applicable rates set forth in Exhibit C for such Contractor non-craft employees.

 

  (b)

Craft Direct Labor Costs” means, with respect to each category of Contractor’s craft employees identified in Exhibit C and the Personnel Authorization Assignment Form (PAAF), (i) the actual, verifiable and documented hours worked by such Contractor craft employees in the performance the Reimbursable Work multiplied by (ii) the applicable rates set forth in Exhibit C for such Contractor craft employees.

 

  1.1.2

Other Direct Costs” means the actual, verifiable and documented expenditures, other than (i) Direct Labor Costs (which shall be paid in accordance with Section 1.1.1 above even when incurred in connection with (a) through (ee) below); and (ii) Contractor’s G&A (described in Section 3 below), incurred by Contractor while performing the Reimbursable Work, excluding in all cases any Non-Reimbursable Costs. Other Direct Costs include all costs incurred in connection with the Work including, without limitation, the following items, without duplication, unless such items are expressly stated to be Non-Reimbursable Costs:

 

  (a)

Facility expenses (including all payments made by Contractor to Subcontractors in connection with the performance of the Reimbursable Work), less amounts reimbursed or credited to Contractor by Subcontractors (including back charges for Work performed by Contractor to complete Subcontractor work or remedy Subcontractor Defects and Deficiencies, liquidated damages or otherwise);

 

  (b)

the cost of all Materials, plus related transportation, temporary storage for logistics receiving, protection and preservation, services of freight forwarding agents including logistics, boxing, packing, export preparation, customs clearance and import duties required for the performance of the Reimbursable Work;

 

1


Execution Version

 

  (c)

the cost of Permits required to be obtained by Contractor in the performance of the Reimbursable Work;

 

  (d)

the costs of third party consultants, subject to Owner’s prior approval (such approval not to be unreasonably withheld), and of manufacturers’ supervisors, service and commissioning engineer / technicians and vendor service representatives required by Contractor to perform the Reimbursable Work;

 

  (e)

the cost of inspection fees or other fees paid to Government Authorities or third party inspectors, required by Government Authorities to be paid by Contractor in the performance of the Reimbursable Work;

 

  (f)

Contractor Taxes as provided for in Section 34.1 of the Agreement;

 

  (g)

Specialized computer software or licenses, subject to Owner’s prior approval;

 

  (h)

all costs incurred by Contractor for repairing or replacing Defects or Deficiencies as provided for in Section 20.1.1 of the Agreement, including Subcontractor costs to repair or replace Defects or Deficiencies (to the extent payable to Subcontractors) and the cost of the enforcement of Subcontractor warranties with respect to the Reimbursable Work;

 

  (i)

all costs incurred by Contractor for remedying physical damage to the Reimbursable Work or the property of Owner, its Affiliates, Owners Contractors, subcontractors and vendors and any and all costs to remove and reinstall the same;

 

  (j)

currency forward contracts, hedges and options entered into by Contractor with Owner’s prior approval solely with respect to the performance of the Reimbursable Work;

 

  (k)

Contractor staff and craft relocation costs in accordance with Contractor’s relocation policy, as provided to Owner in writing and approved by Owner (such approval not to be unreasonably withheld), cost of living adjustment, uplifts, incentives, travel and subsistence expenses, per diem, safety and performance incentives, in each case, only if such costs were incurred by Contractor in connection with the performance of the Reimbursable Work;

 

  (l)

Staff travel expenses reasonably required to perform the Reimbursable Work, including temporary duty costs, audits, and meetings at the Job Site or Owner’s offices. Travel costs for international travel that is required to perform the Reimbursable Work shall be pre-authorized by Owner. Travel shall be consistent with Contractor standard procedures, Owner Standards and subject to the following requirements:

 

  (1)

travel policies approved by Owner;

 

2


Execution Version

 

  (2)

travel time shall be billed at the applicable labor billing rate set forth in Exhibit C and the Personnel Authorization Assignment Form (PAAF), unless pre-authorized in writing by Owner; and

 

  (3)

mileage for personal vehicles shall be billed per Contractor’s normal mileage reimbursement policy.

 

  (m)

NOT USED;

 

  (n)

Job Site infrastructure, offices, lay down areas, temporary facilities (including offices, furnishings, fixtures, utilities, sewer, firewater systems and water), lunchrooms, craft support, facilities, safety facilities, safety and QA/QC equipment and testing apparatus, security, first aid, site cleaning or clearing as required, trash disposal, sanitary facilities, janitorial services, photography, model photographs, general drawing and office supplies (including but not limited to paper, pencils, pens, file folders, printed forms, stationary, paper cutters, staplers, drawing racks and computer discs), communications, reproduction or other graphic services, copy machines (including installation and maintenance) and all other equipment, materials, and specialty items and services required to complete the Reimbursable Work;

 

  (o)

Hourly rates or unit rates, as specified in Exhibit C, incurred in connection with Reimbursable Work including module fabrication, ship offloading of Owner Furnished Equipment and Materials and barge transfer of modules to barges for transport to the Job Site. Hourly rates and unit rates shall apply equally and without adjustment to performance of all Work, regardless of (i) large or small quantities, (ii) elevations, (iii) positions within any applicable Facility module or component, (iv) location within the Job Site, (v) accessibility, (vi) constraints of the work permit system and Commissioning activities or (vii) and any other factor that would affect productivity in the completion of the applicable Work, including Work executed on transportation barges;

 

  (p)

Contractor and Subcontractor cost of construction equipment, including equipment on standby as defined in the Facility equipment plan and equipment for Pre- Commissioning, Commissioning and start-up at the Job Site, required to perform the Reimbursable Work. Owner approval shall be required for the Facility equipment plan and any stand-by other than short term stand-by of equipment; when stand-by is not approved then demobilization and remobilization costs shall be applicable. All Contractor owned equipment shall be charged at the rates set forth in Exhibit C. Construction equipment charges shall be consistent with the following:

 

  (1)

mobilization and demobilization expenses (including unavoidable cancellation charges from Subcontracts upon termination) will be charged to Owner at the

 

3


Execution Version

 

  cost incurred by Contractor for equipment in the Mobilization Plan that is approved by Owner (such approval not to be unreasonably withheld);

 

  (2)

each of (i) tires and tracks using the rates set forth in Exhibit C, (ii) labor and materials for long-term maintenance repairs and other service and repairs, and (iii) fuel, oil, and grease;

 

  (3)

Operators are not included in the stated rates for equipment;

 

  (4)

Third party rentals will be invoiced at cost;

 

  (5)

equipment will not be overhauled/painted prior to removal from the Job Site; and

 

  (6)

Contractor equipment assigned to the Work will be charged to Owner, and shall not exceed fifty (50) hours per week for the first shift unless approved by Owner. Equipment utilized on the approved equipment plan on a second shift shall be billed shall not exceed twenty (20) hours per week unless approved by Owner. To the extent that equipment is equipped with a smart meter that shows actual utilization, and the meter shows utilization of hours in excess of fifty (50) hours for day shift and twenty (20) hours for night shift if assigned, the equipment will be billed based on the actual meter hours. Equipment that is expected to have smart meters includes but not is limited to cranes, dozers, back hoes, roller/vibrators. Equipment charges apply to equipment which is verifiable and documented that is on standby for Work, Owner shall be notified weekly of all equipment on stand-by. To the extent the Contractor decides to pre-stage equipment prior to use, mobilizes equipment without prior Owner authorization, or equipment is stored on the Job Site prior to removal, neither storage nor equipment utilization will be invoiced. Contractor shall notify Owner of all pre-stage or stored equipment on the Job Site. Contractor shall provide a copy of the approved Mobilization Plan, proof of equipment utilization in the form of weekly equipment utilization summary timesheets signed by authorized Owner personnel for all equipment utilized. In the event equipment is approved for standby by Owner, equipment charges, as set forth in Exhibit C, shall apply. In order to substantiate equipment charges in Contractor’s invoice, Contractor shall provide proof of standby authorization, and provide weekly summary timesheet signed by Company authorized personnel for all equipment on standby.

 

  (q)

commodities, supplies, rental tools, loss or damage to tools not included with ST&S, re-assembly of equipment after inspections or transportation, consumables, skip boxes, scaffolding replacement components, Connex and freight containers, and personnel protective equipment;

 

  (r)

costs of commercial testing and inspection laboratories, soils testing and analysis consultants, x-ray testing/NDE/NDT, concrete and soil testing, stress relieving kits and supplies, etc. and similar third-party services required for the performance of the Reimbursable Work;

 

4


Execution Version

 

  (s)

rental costs for vehicles for Contractor personnel necessary for the performance of the Reimbursable Work, only if such rental costs were incurred in compliance with Contractor’s vehicle rental policy, Owner’s Standards and per Owner’s prior approval with respect to any changes to the vehicle rental policy or equipment plan. Aggregate rental costs for any vehicle shall not exceed the vehicle’s fair market value;

 

  (t)

Hazardous Substance cleanup, subject to the limitations set forth in Section 3.8.46 and Section 30.1.2 of the Agreement;

 

  (u)

miscellaneous Job Site expenses necessary to perform the Reimbursable Work, including expenses to acquire, purchase, lease or pay for furniture, phones, copiers, printers, plotters, facsimile equipment, mail service, internet service, computers, training materials and equipment, networks, courier services, internal and external photocopying, related petty cash items, temporary facilities and supplies, utilities, miscellaneous Job Site services, specialty software requested by Owner or not normally used by Contractor and software maintenance (so long as notified to Owner prior to use);

 

  (v)

Facility-specific entertainment and incentives consistent with Contractor policies, with any expense exceeding [***] per event requiring Owner’s prior approval;

 

  (w)

consumable spares and fluid fills of lubricants, all liquids and chemicals such as catalysts, chemicals, water, nitrogen, coolants, greases, lubricants, refrigerants and any topping off of these items and similar supplies, in each case required for construction, Pre-Commissioning, Commissioning and start-up;

 

  (x)

Safety supplies and equipment (including PPE) for the Reimbursable Work;

 

  (y)

costs incurred in replacing operating and Commissioning Spare Parts borrowed from Owner’s inventory (excluding Spare Parts used in connection with Corrective Work);

 

  (z)

costs incurred in obtaining and maintaining Facility-specific insurance policies required under the Agreement;

 

  (aa)

costs of Facility-specific project attorney personnel hours and expenses as well as external attorney and claims consultant costs (specifically including for Subcontractor and Agent For Contractor claims) incurred by Contractor while performing the Reimbursable Work as provided for in Section 23.1.4 of the Agreement, but excluding attorney hours and expenses attendant to any dispute between Owner and Contractor/Guarantor arising under the Agreement or the Contractor Guarantee;

 

5


Execution Version

 

  (bb)

costs to provide the Performance and Payment Bonds to Owner required under Section 9.2.1 of the Agreement;

 

  (cc)

costs incurred by Contractor for Permitted Liens;

 

  (dd)

uninsured losses and deductibles described in the Agreement; and

 

  (ee)

costs associated with Subcontractor and Agent For Contractor change orders and claims including all settlement amounts, as provided for in Section 23.1.4 of the Agreement, to the extent not addressed in clause (aa).

Notes:

1. If there is no applicable rate contained in Exhibit C to the Agreement for any item, then a new rate shall be agreed by pro-rating, extrapolating or interpolating from rates for similar work contained within Exhibit C to the Agreement. Should there be no similar items, a new rate shall be calculated from analysis agreed between Owner and Contractor based on similar labor productivity to that in the rates in Exhibit C to the Agreement. The Contractor shall provide sufficient detail to demonstrate that the labor productivity used for new rates is compatible with those used in the Agreement. Once agreed, the new rates shall remain valid for the duration of one year and be adjusted yearly thereafter in accordance with Exhibit C.

2. In the event Contractor incurs a Direct Cost in a currency other than Dollars, Contractor shall convert the amount of such Direct Cost to Dollars using the official rate of foreign exchange between such currency and the Dollar published by the central bank or comparable national monetary authority of the jurisdiction to which such other currency relates on the Business Day immediately preceding the day on which such Direct Cost is invoiced to Owner in a Request for Payment. Contractor shall include details of the calculation of such rate of foreign exchange together with the relevant Request for Payment. In no event shall Owner be responsible for Contractor’s foreign exchange hedging costs or other currency hedges except to the extent approved in accordance with clause (j) above.

 

2.

Non-Reimbursable Costs.

Non-Reimbursable Costs include costs or expenses incurred by Contractor related to the following items:

 

  (a)

Taxes based on or related to the net income, capital or net worth of Contractor or any Subcontractor;

 

6


Execution Version

 

  (b)

costs and expenses incurred in connection with corporate training recruiting and corporate meetings not directly related to the Work, or public and/or business relations not directly related to the Work;

 

  (c)

Liquidated damages required to be paid under the Agreement;

 

  (d)

Amounts required to be paid under Section 5.1.2, Section 30.1.2 or Section 40.3.2 of the Agreement;

 

  (e)

Any costs, expenses or other items included in Contractor’s G&A as listed in Section 3 below;

 

  (f)

Any additional general and administrative expenses, fees or mark-up of a Contractor Affiliate;

 

  (g)

Sales and use taxes on construction owned equipment and Contractor’s machinery, materials and other equipment to the extent not constituting a Direct Cost;

 

  (h)

Owner Costs and Direct Costs for Indemnified Liens;

 

  (i)

Owner Costs and Direct Costs to discharge and settle Subcontractor and Agent For Contractor claims arising from and solely attributable to the Gross Negligence or Willful Misconduct of Senior Supervisory Personnel;

 

  (j)

Costs, fees and expenses incurred by Contractor or required to be paid to Owner to the extent of Contractor’s obligations under Sections 30.1.1, 30.1.2 and 30.1.3 of the Agreement;

 

  (k)

Amounts required to be paid by Contractor under Section 31.3 of the Agreement, it being understood that such amounts shall not be treated as a Non-Reimbursable Cost for the purposes of Section 21.1(e) of the Agreement;

 

  (l)

incidental, indirect, punitive or consequential damages or for loss of profit, product, revenue, contract or use to the extent waived by Owner pursuant to Section 21.2 of the Agreement;

 

  (m)

Corrective Work performed during any Warranty Period in respect of which Substantial Completion was achieved prior to termination;

 

  (n)

costs and expenses of any work outside the Scope of Work described in Exhibit A of the Agreement that was performed by Contractor prior to its having received an executed Change Order or authorization from Owner;

 

  (o)

costs and expenses of performing that portion of the Work that Contractor knows to be a violation to any Laws or Permits;

 

7


Execution Version

 

  (p)

Contractor’s repayment to Owner of amounts previously paid by Owner under this Agreement that were determined to be a Non-Reimbursable Cost;

 

  (q)

costs and expenses incurred by Contractor in connection with Section 30.1.1 of the Agreement;

 

  (r)

costs of attorney hours and expenses attendant to any dispute between Owner and Contractor/Guarantor arising under the Agreement or the Contractor Guarantee;

 

  (s)

the amount of any arbitral award rendered in favor of Owner under Section 36.1.3 of the Agreement and the costs of such arbitration to the extent it is determined by the tribunal that Contractor should be responsible for such costs; it being understood that such amounts shall not be treated as a Non-Reimbursable Cost for the purposes of Section 21.1(e) of the Agreement;

 

  (t)

Contractor’s capital or financing costs, including principal or interest on capital used for performance of the Work;

 

  (u)

Amounts that Contractor is obligated to reimburse to Owner specified within the Agreement;

 

  (v)

charitable contributions, unless approved in advance by Owner;

 

  (w)

Contractor’s costs incurred to achieve the “make good” obligations under Section 15.3.4 of the Agreement, except as provided in Section 15.3.4 of the Agreement;

 

  (x)

any cost or expense described in Section 1 that (1) is not auditable and verifiable by Contractor’s accounts and records or (2) was improperly incurred without Owner’s approval where required;

 

  (y)

any cost or expense paid to a Subcontractor that was not due and owing to such Subcontractor in accordance with the express terms of the relevant Subcontract or this Agreement; and

 

  (z)

per-occurrence costs or expenses exceeding One Thousand Dollars ($1000) incurred by Contractor or any Subcontractor for dinners, lunches, social events or team building event, to the extent not approved by Owner.

 

3.

Contractor’s G&A

A multiplier of (i) [***] for all Direct Costs (other than Tax Costs) and (ii) [***] for all Tax Costs (each the “G&A Multiplier”) will be applied across all Direct Costs for G&A recovery in accordance with the definition of Contractor’s G&A . The G&A Multiplier will recover the following overhead costs:

 

  a)

Home Office Executive Management

 

  b)

Corporate Equipment Administration

 

8


Execution Version

 

  c)

Marketing

 

  d)

Corporate Accounting/Financial Reporting/Financial Analysis

 

  e)

Corporate Risk Management Staff

 

  f)

Human Resources (excluding Facility assigned Human Resources staff)

 

  g)

Corporate Tax Staff (unless addressing Owner tax benefits)

 

 

  h)

Corporate I/T Staff and I/T Infrastructure

 

  i)

Corporate Treasury/Cash Management

 

  j)

Internal Audit

 

  k)

Corporate Training and Corporate Events

 

  l)

Division and District Managers

 

  m)

Corporate Legal Staff (non Facility-specific)

 

  n)

Employee Benefit Administration

 

  o)

Corporate offices and Corporate vehicles

 

  p)

Corporate telecommunications and computer hardware

 

  q)

Corporate Software and licenses

In no event shall the G&A Multiplier apply to any general and administrative expenses, fees or mark-up of a Contractor Affiliate, except for those items in 1.1.1 of this Exhibit B-1.

 

9


Execution Version

 

EXHIBIT B-2

[RESERVED]

[NOT USED]

 

1


Execution Version

 

EXHIBIT B-3

TARGET PRICE COMPONENTS

 

Direct Costs:   [***]
Contractor’s G&A:   [***]
Contractor’s Margin:   [***]
 

 

Target Price:   [***]

 

1


Execution Version

 

EXHIBIT B-4

COVER COSTS EXAMPLES

[Omitted]

 

1


EXHIBIT B-5

PAYMENT PROCEDURES

[Omitted]

 

1


Execution Version

 

EXHIBIT C

CONTRACTOR RATES

[Omitted]

 

1


Execution Version

 

EXHIBIT D

SCHEDULE MILESTONES

[Omitted]

 

1


Execution Version

 

EXHIBIT E

PROJECT SCHEDULE

[Omitted]

 

1


Execution Version

 

EXHIBIT F

CONTRACT FORMS

[Omitted]

 

1


Execution Version

 

EXHIBIT F-1

FORM OF CONTRACTOR CERTIFICATE FOR PARTIAL WAIVER OF LIENS

[Omitted]


Execution Version

 

EXHIBIT F-2

FORM OF SUBCONTRACTOR CERTIFICATE FOR PARTIAL WAIVER OF LIENS

[Omitted]


Execution Version

 

EXHIBIT F-3

FORM OF CONTRACTOR CERTIFICATE FOR FINAL WAIVER OF LIENS

[Omitted]


Execution Version

 

EXHIBIT F-4

FORM OF SUBCONTRACTOR CERTIFICATE FOR FINAL WAIVER OF LIENS

[Omitted]


Execution Version

 

EXHIBIT F-5

FORM OF CONSENT AND AGREEMENT

[Omitted]


Execution Version

 

EXHIBIT F-6

FORM OF CONTRACTOR GUARANTEE

[Omitted]


Execution Version

 

EXHIBIT F-7

FORM OF REQUEST FOR PAYMENT

[Omitted]


Execution Version

 

EXHIBIT F-8

FORM OF LIMITED NOTICE TO PROCEED

[Omitted]


Execution Version

 

EXHIBIT F-9A

PERFORMANCE BOND

[Omitted]


EXHIBIT F-9B

FORM OF PAYMENT BOND

[Omitted]


Execution Version

 

EXHIBIT F-10

FORM OF CHANGE ORDER

[Omitted]


Execution Version

 

EXHIBIT F-11

FORM OF LNG PRODUCTION SYSTEM

MECHANICAL COMPLETION CERTIFICATE

[Omitted]


Execution Version

 

EXHIBIT F-12

FORM OF LNG PRODUCTION SYSTEM RFSU CERTIFICATE

[Omitted]


Execution Version

 

EXHIBIT F-13

FORM OF NOTICE TO PROCEED

[Omitted]


Execution Version

 

EXHIBIT F-14

FORM OF TITLE INSURANCE INDEMNITY AGREEMENT UNDERTAKING

[Omitted]


Execution Version

 

EXHIBIT F-15

FORM OF PAYMENT STATUS AFFIDAVIT

[Omitted]


Execution Version

 

EXHIBIT F-16

FORM OF SUBCONTRACTOR’S PAYMENT STATUS AFFIDAVIT

[Omitted]


Execution Version

 

EXHIBIT F-17

FORM OF CERTIFICATE OF ACHIEVEMENT

[Omitted]


Execution Version

 

EXHIBIT F-18

FORM OF CERTIFICATE OF SCHEDULE MILESTONE ACHIEVEMENT

[Omitted]


Execution Version

 

EXHIBIT G

TRAINING REQUIREMENTS

[Omitted]

 

1


Execution Version

 

EXHIBIT H

SCHEDULE OF MAJOR VENDORS

[Omitted]

 

1


Execution Version

 

EXHIBIT I

PROGRESS REPORTING AND PROJECT MEETINGS

[Omitted]

 

1


Execution Version

 

EXHIBIT J

DOCUMENT CONTROL AND INFORMATION MANAGEMENT

[Omitted]

 

1


Execution Version

 

EXHIBIT K

LIST OF CONTRACTOR’S KEY PERSONNEL

[Omitted]

 

1


Execution Version

 

EXHIBIT L

PERMITS, LICENSES AND GOVERNMENT APPROVALS

[Omitted]

 

1


Execution Version

 

EXHIBIT M

RELIED UPON INFORMATION

[Omitted]

 

1


EXHIBIT N

OWNER SUPPLIED INFORMATION

[NOT USED]

 

1


Execution Version

 

EXHIBIT O

SCHEDULE OF MAJOR SUBCONTRACTORS

[Omitted]

 

1


Execution Version

 

EXHIBIT P

MECHANICAL COMPLETION, COMMISSIONING, START-UP AND

SUBSTANTIAL COMPLETION

[Omitted]

 

1


Execution Version

 

EXHIBIT Q

OWNER PERSONNEL

[Omitted]

 

1


Execution Version

 

EXHIBIT R

DEMONSTRATION TESTS AND PERFORMANCE TESTS

[Omitted]

 

1


EXHIBIT S

LNG PRODUCTION SYSTEM HANDOVER PACKAGES

[Omitted]

 

1


Execution Version

 

EXHIBIT T

REQUIREMENTS FOR SIMULTANEOUS OPERATIONS

[Omitted]

 

1


Execution Version

 

EXHIBIT U

HEALTH, SAFETY, SECURITY AND ENVIRONMENTAL REQUIREMENTS

[Omitted]

 

1


Execution Version

 

EXHIBIT V

FIRST FILLS AND CATALYSTS

[Omitted]

 

1


Execution Version

 

EXHIBIT W

OPEN COST ITEMS

[Omitted]

 

1


EXHIBIT X

COST OVERRUN AND COST SAVING ADJUSTMENTS

The purpose of this Exhibit is to describe the process for calculating the amount of any adjustment to the cost overrun and cost saving values in Section 8.2.1 and Section 8.3.1 of the Agreement, respectively (the “Values”), on the basis of any changes in the cost of craft labor, craft per diem, subcontracts, materials and equipment. For additional clarification, Staff Labor escalation is already included in the Target Price in accordance with Exhibit C and is not entitled to adjustment. This Exhibit X does not address the adjustments to the Project Schedule that may be required under Article 12 of the Agreement.

Adjustment Principals

 

   

The Values will be increased or decreased based on the adjustments to the cost of subcontracts, materials and equipment determined pursuant to this Exhibit X. A cost adjustment (as defined below) will result in an adjustment to the Values in Section 8.2.1 and to the Values in Section 8.3.1 of the Agreement.

 

   

If the maximum cumulative adjustment is determined to be less than [***], the Values shall not be adjusted.

Craft Labor and Craft Per Diem

Rates in Exhibit C are valid through Final Substantial Completion but can be modified as follows:

For Craft Labor and Craft Per Diem escalation, and in accordance with Exhibit C-2.1 and C-4.0, the following will be used to analyze and determine if an adjustment is warranted. Any such agreed adjustment to the craft labor and or per diem rates shall be documented in a letter agreement between the Parties and implemented via the project trending process, which shall be effective to adjust the rates in Exhibit C-2.1 and C-4.0. Any such letter agreement documenting a craft labor and or per diem rate adjustment shall also document a corresponding adjustment to the Values in Section 8.2.1 and Section 8.3.1, which shall be determined by multiplying the agreed adjustment by the relevant forecasted craft hours remaining in the relevant craft labor categories.

Contractor shall continually monitor craft labor market conditions including wage and per diem (craft compensation) trends in the US Gulf Coast during the construction phase of the Project. If Contractor reasonably believes through evaluation of data (listed below) that the craft labor rates and / or per diem rates need to be adjusted in order to appropriately staff the Project in alignment with expected rates (requisition fill time, absenteeism, turn over), it shall propose such adjustments to the craft labor rates and or per diem in Exhibit C-2.1 and C-4.0. The Parties will promptly meet, review the data developed by the Contractor and the proposed adjustments to the craft labor rates and or per diem as required, which proposed adjustment shall not be unreasonably denied. At a minimum the analysis shall be based on the following:

 

1


   

Wage rate and per diem indices prepared by Alpha Resources (or other provider, local or regional consultants, competitor wage surveys, competing projects actual compensation reports as approved by Owner) and,

 

   

Project employment metrics provided by Contractor relating to project specific turnover, absenteeism, productivity rates, requisition fill times, and forecasted labor needs.

Subcontracts, Materials and Equipment Adjustment

 

   

The review of aggregate adjustments shall not be done more frequently than a quarterly basis commencing with Notice to Proceed.

 

   

The Owner and the Contractor shall agree to the index or indices for every material, equipment, or subcontract package greater than [***] dollars within [***] days of the Effective Date. If an individual package is less than [***], it is not subject to adjustment.

 

   

The calculation of an index adjustment shall be determined by taking the original estimated cost of the package and multiplying by the change in the index value from the effective date and the package award date.

 

   

The adjustment will be based on the lesser of the actual price for the package, or the impact of the agreed upon index or indices for that package; minus all estimate error, estimate miss, estimate omission, design development, quantity growth or Owner directed change values.

 

   

If the adjustment of any individual package is deemed less than [***], no adjustment will be made.

 

   

Materials pricing shall be adjusted by the percentage change in the relevant commodity reflected in the Nucor Steel Pricing or IHS Market analysis.

Procedure

 

   

Within [***] days following the Effective Date, and then no more frequently than a quarterly basis thereafter, the Contractor shall provide an updated listing of all material, procurement, or subcontract packages greater than [***].

 

   

The listing shall include package, WBS Code(s), original budget value, original quantity(s), award quantity(s), award value, award date, index or indices, and values of adjustments for estimate error, estimate miss, estimate omission, design development, quantity growth or Owner directed change values, net reduction value, net adjustment value (award value less reductions).

 

2


Examples

[***]

 

3


Execution Version

 

EXHIBIT Y

COORDINATION PROCEDURE

[Omitted]

 

1


EXHIBIT Z

CP2 PHASE 2 EPC TERM SHEET

[Omitted]

Exhibit 10.23

Execution Version

EXHIBIT F-6

FORM OF CONTRACTOR GUARANTEE

This GUARANTY, dated as of June 8, 2023 (this “Guaranty”), is made by WORLEY LIMITED, a company limited by shares incorporated in Australia (“Guarantor”), for the benefit of VENTURE GLOBAL CP2 LNG, LLC, a Delaware Limited Liability Company (the “Beneficiary”). The Guarantor and Beneficiary are referred to herein individually as a “Party” and collectively as the “Parties”.

RECITALS

WHEREAS, the execution and delivery of this Guaranty is required pursuant to Section 9.3 of that certain Engineering, Procurement and Construction Agreement (as may be amended, modified or supplemented from time to time, the “Agreement”), dated as of the date hereof, by and between Worley Field Services Inc., a Texas corporation (“Obligor”) and Beneficiary;

WHEREAS, this Guaranty is entered into by the Guarantor as an inducement for Beneficiary to enter into and consummate the transactions contemplated by the Agreement; and

WHEREAS, Guarantor will derive substantial benefit from the consummation of the transactions contemplated by the Agreement.

NOW, THEREFORE, in consideration of the mutual covenants contained herein and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Guarantor and Beneficiary agree as follows:

ARTICLE 1

DEFINITIONS AND CONSTRUCTION

1.1 Defl11itio11s. All capitalized terms used but not defined herein shall have the meanings set forth for such terms in the Agreement.

ARTICLE 2

GUARANTY

2.1 Guaranty. Guarantor hereby irrevocably, absolutely, fully and unconditionally guarantees to Beneficiary and its successors and assigns the timely and complete payment and performance when and as due (whether at the stated due date, by acceleration or otherwise) of all obligations of Obligor arising under the Agreement (the “Guaranteed Obligations”), subject to the limitations and rights of Obligor set forth in the Agreement.

2.2 No Release or Discharge. This Guaranty is a direct and primary obligation of Guarantor and shall be an irrevocable, unconditional, absolute and continuing guaranty, irrespective of the following potential defenses:

2.2.1 any invalidity, voidability or unenforceability of, or defect or deficiency applicable to Obligor in respect of, the Agreement or any other documents executed in connection with the Agreement based on Obligor’s lack of corporate power and authority to enter


Execution Version

 

into the Agreement or such other documents or the failure of the Agreement or such other documents to be duly authorized and executed by Obligor and its signatories;

2.2.2 any postponement or extension of the date on which any payment must be made pursuant to the Agreement or postponement or extension of the date on which any act must be performed by Obligor thereunder, provided that any such postponement or extension shall be deemed to apply to the Guarantor’s obligations hereunder in the same way that it applies to Obligor’s obligations under the Agreement;

2.2.3 whether or not Guarantor received direct notice of or consented to any modification, amendment, supplement, renewal or waiver of the Agreement or any of the terms or conditions of the Agreement, including under a Change Order, provided that the Guaranteed Obligations shall not be greater than the obligations of Obligor under the Agreement, as the Agreement may be so modified, amended, supplemented, renewed or waived without Guarantor’s consent;

2.2.4 any failure, omission or delay on the part of Beneficiary or any other Person to confirm or comply with any of the terms or conditions of the Agreement or any other documents executed in connection with the Agreement;

2.2.5 except as to applicable statutes of limitation or other contractual period of limitation, the failure, omission, delay, or refusal by Beneficiary to exercise against Obligor, in whole or in part, any right or remedy held by Beneficiary with respect to the Agreement;

2.2.6 any legal disability of Guarantor, or any release or discharge of Guarantor by a bankruptcy court;

2.2.7 any stay applicable to any enforcement of the Guaranteed Obligations against Obligor;

2.2.8 any rights of subrogation, reimbursement, indemnity or contribution that Guarantor or Beneficiary may have against Obligor;

2.2.9 any lack of knowledge by Guarantor as to the condition (including financial) of Obligor, since Guarantor shall be responsible for obtaining its own knowledge of such condition;

2.2.10 any election of remedies by Beneficiary, even if such election of remedies impairs or destroys Guarantor’s right of subrogation against Obligor;

2.2.11 any merger, consolidation, termination of or change in corporate existence, structure or ownership of Obligor or Guarantor, or any insolvency, bankruptcy, reorganization or other similar proceeding affecting Obligor or its assets; or

2.2.12 subject to the defenses available to Guarantor pursuant to Section 2.6.2, any other occurrence or circumstance which might otherwise constitute a legal or equitable discharge or defense of a guarantor or which might otherwise limit recourse against Guarantor all


Execution Version

 

without notice to or further assent by Guarantor, who shall remain bound by this Guaranty, which shall remain in full force and effect until all of the Guaranteed Obligations have been paid in full or otherwise extinguished.

No action which Beneficiary shall take or fail to take in connection with the Guaranteed Obligations, nor any course of dealing with Obligor or any other person, shall release Guarantor’s obligations hereunder, affect this Guaranty in any way, or afford Guarantor any recourse against Beneficiary. This Guaranty is in no way conditioned or contingent upon any attempt to collect from or enforce performance or payment by Obligor or upon any other event, contingency or circumstance whatsoever. Beneficiary shall not be obligated to take any action, obtain any judgment or file any claim prior to enforcing this Guarantee. Beneficiary shall not be obligated to file any claim relating to the Obligations in the event that Obligor becomes subject to a bankruptcy, reorganization or similar proceeding, and the failure of Beneficiary to so file shall not affect Guarantor’s obligations hereunder.

This Guaranty shall continue to be effective or be reinstated, as the case may be, if at any time any payment of any of the Guaranteed Obligations are annulled, set aside, invalidated, declared to be fraudulent or preferential, rescinded or must otherwise be returned, refunded or repaid by Beneficiary upon the insolvency, bankruptcy, dissolution, liquidation or reorganization of Obligor or any other guarantor, or upon or as a result of the appointment of a receiver or conservator of, or trustee for Obligor or any other guarantor or any substantial part of its property or otherwise, all as though such payment or payments had not been made

2.3 Waiver of Rights. Subject to the limitations expressly set forth in this Guaranty, Guarantor understands and agrees that the guaranty contained in Section 2.1 shall be a continuing guaranty. Guarantor hereby expressly waives.

2.3.1 notice of acceptance of this Guaranty, of the creation or existence of any of the Guaranteed Obligations, of any of the matters described in Section 2.2 and of any action by Beneficiary in reliance hereon or in connection herewith;

2.3.2 notice of the entry into the Agreement between Obligor and Beneficiary and of any amendments, supplements or modifications thereto; or any waiver of consent under the Agreement, including waivers of the payment and performance of the obligations thereunder;

2.3.3 notice of any increase, reduction or rearrangement of Obligor’s obligations under the Agreement or any extension of time for the payment of any sums clue and payable to Beneficiary under the Agreement;

2.3.4 presentment, demand for payment, notice of acceptance, notice of dishonor or nonpayment, protest and notice of protest or any other notice with respect to the Guaranteed Obligations; and

2.3.5 any requirement that suit be brought against, or any other remedy or action by Beneficiary be taken against, or any notice of default or other notice be given to, or any demand be made on Obligor or any other person, or that any other action be taken or not taken as


Execution Version

 

a condition to Guarantor’s liability for the Guaranteed Obligations under this Guaranty or as a condition to the enforcement of this Guaranty against Guarantor.

2.4 No Subrogation. Guarantor will not exercise and irrevocably agrees to waive any rights against Obligor which it may acquire by way of subrogation, reimbursement, exoneration, contribution or indemnification in connection with this Guarantee by any payment made hereunder or otherwise, until all Guaranteed Obligations shall have been fully and indefeasibly paid and performed. If (a) Guarantor makes payment to Beneficiary of all or any part of the Guaranteed Obligations and (b) all of the then outstanding Guaranteed Obligations shall have been paid in full, Beneficiary shall, at Guarantor’s request, execute and deliver to Guarantor documents to evidence the transfer by subrogation to Guarantor of any interest in the Guaranteed Obligations resulting from such payment by Guarantor. If any amount shall be paid to Guarantor on account of such subrogation, contribution, reimbursement or indemnity rights at any time when all of the Guaranteed Obligations and all amounts owing hereunder shall not have been performed and paid in full, such amount shall be held by Guarantor in trust for Beneficiary, segregated from other funds of Guarantor, and shall, forthwith upon receipt by Guarantor, be turned over to Beneficiary in the exact form received by Guarantor (duly endorsed by Guarantor to Beneficiary, if required), to be applied against the Guaranteed Obligations, whether or not matured, in such order as Beneficiary may determine.

2.5 Demand and Payment. Beneficiary may provide written notice to Guarantor pursuant to Section 4.1 at any time if Obligor fails to punctually pay or perform any of the Guaranteed Obligations. There are no other requirements of notice, presentment or demand. Guarantor shall pay, or cause to be paid, such Guaranteed Obligations within ten (10) Business Days of receipt of such notice, unless, within such period, the default giving rise to such notice has been remedied. If Beneficiary is prevented from making a demand on Guarantor as a result of any applicable law, any injunction, order or other action of any court or other governmental authority or any stay, moratorium or other action in any bankruptcy, insolvency or other similar proceeding, Guarantor shall not be excused from paying and performing its obligations under this Guarantee as and when due. All payments by Guarantor hereunder shall be paid without setoff or deduction in U.S. dollars in immediately available funds to such accounts as may be designated by Beneficiary from time to time. Guarantor agrees to pay on demand all fees and out of pocket expenses (including the reasonable fees and expenses of Beneficiary’s counsel) in any way relating to the enforcement or protection of the rights of Beneficiary hereunder. Any amount due and payable hereunder shall, if not paid when due, accrue interest at the Late Payment Rate from the date such payment was due until the date such payment is made in full.

2.6 Primary Liability of Guarantor; Guarantor’s Defenses.

2.6.1 Guarantor agrees that Beneficiary may enforce this Guaranty without the necessity at any time of resorting to or exhausting any other security or collateral, or exercising or exhausting any other remedies against Obligor. This is a guaranty of payment and performance when and as due and not merely of collection.

2.6.2 Notwithstanding anything to the contrary stated herein or in the Agreement or any documents related thereto, Guarantor’s undertakings and obligations hereunder with respect to the Agreement are derivative of and not in excess of the Obligor’s


Execution Version

 

obligations under the Agreement and Guarantor may assert as a defense, right of set-off or counterclaim to its obligations hereunder any defense, right of set-off or counterclaim that Obligor may have to such Guaranteed Obligations under the Agreement or otherwise, even if Obligor fails to raise the same, except (i) a defense based on the discharge of the Guaranteed Obligations as to Obligor in a bankruptcy or insolvency proceeding or (ii) other defenses expressly waived hereunder.

2.7 Continuing Guaranty. Guarantor’s obligations under Section 2.1 of this Guaranty shall continue in force and effect until the Guaranteed Obligations have been fully performed or otherwise extinguished under the Agreement, at which time this Guaranty and all of Guarantor’s obligations hereunder shall terminate and expire. Guarantor agrees that any judgment between Obligor and Beneficiary under the Agreement (whether in contested litigation or arbitration or otherwise) shall be conclusive and binding on Guarantor for the purposes of determining Guarantor’s obligations under this Guaranty.

2.8 Guarantor Financial Statements. As soon as available, but in any event no later than one-hundred twenty (120) Days after the end of each applicable six (6)-month period, Guarantor shall make available to Beneficiary a copy of the audited consolidated balance sheets at the end of each such period as well as the related consolidated statements of income, retained earnings, and cash flows for such period. All financial statements delivered pursuant to this Section 2.8 shall be complete and correct in all material respects and shall be prepared in accordance with A-IFRS applied consistently throughout the periods reflected therein. If the Guarantor makes the foregoing financial statements publicly available on its website or through filings pursuant to applicable securities laws, then the requirements of this Section 2.8 shall be deemed met by the Guarantor making such financial statements publicly available in accordance with the requirements of applicable securities laws or, otherwise, in accordance with its customary practice.

ARTICLE 3

REPRESENTATIONS AND WARRANTIES

3.1 Representations and Warranties of Guarantor. Guarantor represents and warrants as follows:

3.1.1 It is a company limited by shares, duly incorporated, validly existing and in good standing under the laws of Australia.

3.1.2 It has all requisite power and authority to execute and deliver this Guaranty and to perform all obligations to be performed by it hereunder. The execution and delivery of this Guaranty and the consummation of the transactions contemplated hereby have been duly and validly authorized and approved by all requisite limited partnership action on its part. This Guaranty has been duly and validly executed and delivered by it and this Guaranty constitutes a valid and binding obligation of it, enforceable against it in accordance with its terms.

3.1.3 The execution and delivery of this Guaranty by it and the performance of its obligations hereunder by it do not and shall not: (i) violate any Applicable Law


Execution Version

 

or require any filing with, consent, approval or authorization of, or notice to, any Governmental Authority or any other Person, except as otherwise obtained prior to the date hereof, (ii) violate any of its organizational documents or (iii) breach or conflict with any material contract to which it is a party or by which it may be bound, result in the termination of any such material contract, result in the creation of any lien upon any of its assets or constitute an event which, after notice or lapse of time or both, would result in any such breach, termination or creation of a lien upon any of its assets.

ARTICLE 4

MISCELLANEOUS

4.1 Notices. All notices and other communications required or permitted to be given by any provision of this Guaranty shall be in writing and mailed (certified or registered mail, postage prepaid, return receipt requested) or sent by hand or overnight courier, or by facsimile transmission (with acknowledgment received), charges prepaid and addressed to the intended recipient as follows, or to such other addresses or numbers as may be specified by a Party from time to time by like notice to the other parties:

If to Guarantor, at:

If to Beneficiary, at:

All notices and other communications given in accordance with the provisions of this Guaranty shall be deemed to have been given and received: (i) when delivered, if delivered by hand or transmitted by facsimile (with acknowledgment received); (ii) five (5) Business Days after the same are sent by certified or registered mail, postage prepaid, return receipt requested; or (iii) one (I) Business Day after the same are sent by a reliable overnight courier service, with acknowledgment of receipt.


Execution Version

 

4.2 Assignment. This Guaranty shall be binding upon and inure to the benefit of the Parties and their respective successors and permitted assigns. Neither Party may assign (by contract, stock sale, operation of law or otherwise) either this Guaranty or any of its rights, interests, or obligations hereunder without the express prior written consent of the other Party, and any attempted assignment, without such consent, shall be null and void; provided, however that Beneficiary may assign this Agreement, without the consent of Guarantor (but with written notice to Guarantor) in connection with (i) an assignment of the Agreement by Beneficiary permitted under the Agreement or (ii) a collateral assignment of this Guaranty by Beneficiary to any Lender.

4.3 Rights of Third Parties. Nothing expressed or implied in this Guaranty is intended or shall be construed to confer upon or give any Person, other than Beneficiary, any right or remedies under or by reason of this Guaranty.

4.4 Entire Agreement. This Guaranty constitutes the entire agreement between the Parties with respect to the subject matter hereof and supersedes any prior understandings, negotiations, agreements, or representations between the Parties of any nature, whether written or oral, to the extent they relate in any way to the subject matter hereof.

4.5 Counterparts. This Guaranty may be executed in any number of counterparts, each of which shall be deemed an original but all of which together will constitute one and the same instrument.

4.6 Amendments. This Guaranty may be amended or modified in whole or in part, and terms and conditions may be waived, only by a duly authorized agreement executed by Guarantor and Beneficiary which makes reference to this Guaranty.

4.7 Severability. If any provision of this Guaranty or the application of any such provision to any Person or circumstance shall be declared by any court of competent jurisdiction to be invalid, illegal, void or unenforceable in any respect, all other provisions of this Guaranty, or the application of such provision to Persons or circumstances other than those as to which it has been held invalid, illegal, void or unenforceable, shall nevertheless remain in full force and effect and will in no way be affected, impaired or invalidated thereby. Upon such determination that any provision, or the application of any such provision, is invalid, illegal, void or unenforceable, the parties shall negotiate in good faith to modify this Guaranty so as to effect the original intent of the parties as closely as possible to the fullest extent permitted by Applicable Law in an acceptable manner to the end that the transactions contemplated hereby are fulfilled to the greatest extent possible.

4.8 Financing. Guarantor acknowledges that Beneficiary intends to obtain financing, and Guarantor agrees to cooperate with Beneficiary and the Lenders in connection with such financing, including, but not limited to, entering into a Consent and Agreement with the Lenders, in a form substantially similar to Exhibit F-5 to the Agreement.

4.9 Governing Law; Jurisdiction.

4.9.1 This Guaranty and all claims arising out of or relating to this Guaranty and the transactions contemplated hereby shall be governed by the laws of the State of


Execution Version

 

New York, without regard to the conflicts of law principles that would result in the application of the laws of any other jurisdiction.

4.9.2 Each Party (a) irrevocably submits to the exclusive jurisdiction of any federal court or state court sitting in the Southern District of New York in any dispute, claim or controversy arising under or relating to this Guaranty, (b) agrees that all claims in such action may be decided in such court, (c) waives, to the fullest extent it may effectively do so, the defense of inconvenient forum and (cl) consents to the service of process by mail in accordance with the notice provisions of this Guaranty.

4.9.3 Each Party waives all right to trial by jury in any action or proceeding to enforce or defend any rights under this Guaranty and any document executed in connection herewith.

[signature page follows]


Execution Version

 

IN WITNESS WHEREOF, this Guaranty has been duly executed and delivered by Guarantor as of the date first above written.

 

GUARANTOR
WORLEY LIMITED
By: /s/ Robert Christopher Ashton        
Name: Robert Christopher Ashton
Title: Chief Executive Officer
WORLEY LIMITED
By: /s/ Nuala Maria O’Leary          
Name: Nuala Maria O’Leary
Title: Company Secretary
BENEFICIARY
VENTURE GLOBAL CP2 LNG, LLC
By: /s/ Keith Larson              
Name: Keith Larson
Title: Secretary

 

 

 

[Signature Page -Guaranty]

Exhibit 10.24

(Execution Version)

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER

 

November 9, 2023    Change Order No. 1
   Reference: Exhibit W
   Change Order Request No. SCO-0002

Venture Global CP2 LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware (“Owner”), and Worley Field Services Inc., a corporation duly organized and validly existing under the laws of the State of Texas (“Contractor”), hereby agree to the following change to that certain Engineering, Procurement and Construction Agreement, dated as of May 12, 2023, by and between Owner and Contractor (as amended, supplemented or otherwise modified, the “Agreement”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, agreed upon by the Parties pursuant to Article 12 of the Agreement, is considered an amendment to the Agreement. Except to the extent specifically described in this Change Order, the change(s) set forth herein do(es) not relieve Contractor of its responsibilities set forth in the Agreement.

Provided that this Change Order is executed by both Parties, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Contractor fully for such effects, unless otherwise provided in the detailed description below.

Changes:

The Agreement is hereby modified with the revisions set forth below:

 

  (a)

Article 1 of the Agreement is hereby amended by deleting the defined term “Owner Contracts” in its entirety and replacing it with the following:

““Owner Contracts means:

 

  (1)

the Construction Agreement relating to the Marine Works to be entered into between Owner and TBD;

 

  (2)

the Construction Agreement relating to the Storm Surge Wall to be entered into between Owner and TBD;

 

  (3)

the LTS PO;

 

  (4)

the PIS PO;


(Execution Version)

 

  (5)

the LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 1) dated as of June 22, 2023 between CB&I Storage Tank Solutions LLC and Owner;

 

  (6)

the PTS PO;

 

  (7)

the Pipeline and Gas Gate Station PO;

 

  (8)

the BOG PO;

 

  (9)

the ACC PO;

 

  (10)

the Loading Arms PO; and

 

  (11)

the Loading Pumps PO.”

 

  (b)

Article 1 of the Agreement is hereby amended by deleting the defined term “PIS PO” in its entirety and replacing it with the following:

““PIS PO means the Purchase Order Contract for the Sale of the Power Island System dated as of July 14, 2023 between Owner and BH.”

 

  (c)

Article 1 of the Agreement is hereby amended by inserting the following new defined terms in alphabetical order:

““ACC PO means the purchase order contract for the sale of air cooled condenser units to be entered into by Owner.

BOG PO means the Purchase Order Contract for the sale of BOG Compressor Units dated September 13, 2023 between Siemens Energy Inc. and Owner.

Loading Arms PO means the purchase order contract for the sale of LNG loading arms to be entered into by Owner.

Loading Pumps PO means the purchase order contract for the sale of LNG loading arms to be entered into by Owner.”

 

  (d)

Section 9.2.2 of the Agreement is hereby amended by deleting each reference therein to “Payment Bond” and by inserting a reference to “Performance Bond” in its place.

 

  (e)

Section D (Key Owner Delivery Dates to Support Project Schedule) of Exhibit D (Schedule Milestones) to the Agreement is hereby deleted in its entirety, and the form of Section D of Exhibit D attached hereto as Exhibit A shall be inserted in its place.

 

  (f)

Exhibit W (Open Cost Items) to the Agreement is hereby deleted in its entirety and the form of Exhibit W attached hereto as Exhibit B shall be inserted in its place.


(Execution Version)

 

For the avoidance of doubt, the foregoing shall have no impact on the requirements set forth in Section 15.3.4. and as defined in Exhibit R to the Contract.

Price:

The Parties have agreed to reduce the Target Price by the amount of [***].

 

Initial Target Price:    [***]
Value of Change Order:    [***]

Adjusted Target Price as a result

of this Change Order:

   [***]

Deliverable Schedule:

Except as set forth in section (b) above, this Change Order shall have no impact on the Project Schedule or Applicable Deadlines.

This Change Order is not valid, except as otherwise provided in the Agreement, until fully executed by Contractor and Owner.

[Signatures on the following page.]


(Execution Version)

 

IN WITNESS WHEREOF, the Parties have caused this Change Order to be executed by their duly authorized representatives as of the date and year first above written.

 

Venture Global CP2 LNG, LLC    Worley Field Services Inc.
By: /s/ Keith Larson                 By: /s/ Amanda Knost             
Name: Keith Larson    Name: Amanda Knost
Title: Secretary    Title: President, US Gulf Coast


(Execution Version)

 

Exhibit A

D. Key Owner Delivery Dates to Support Project Schedule.

[Omitted]


(Execution Version)

 

Exhibit B

EXHIBIT W

OPEN COST ITEMS

[Omitted]

Exhibit 10.25

(Execution Version)

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER

 

November 30, 2023    Change Order No. 2
  

Reference: Cement for Soil Stabilization,

Concrete Batch Plants, and Aggregates

   Change Order Request No. SCO-0003

Venture Global CP2 LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware (“Owner”), and Worley Field Services Inc., a corporation duly organized and validly existing under the laws of the State of Texas (“Contractor”), hereby agree to the following change to that certain Engineering, Procurement and Construction Agreement, dated as of May 12, 2023, by and between Owner and Contractor (as amended, supplemented or otherwise modified, the “Agreement”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, agreed upon by the Parties pursuant to Article 12 of the Agreement, is considered an amendment to the Agreement. Except to the extent specifically described in this Change Order, the change(s) set forth herein do(es) not relieve Contractor of its responsibilities set forth in the Agreement.

Provided that this Change Order is executed by both Parties, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Contractor fully for such effects, unless otherwise provided in the detailed description below.

Changes:

The Agreement is hereby modified with the revisions set forth below:

 

  (a)

Article 1 of the Agreement is hereby amended by deleting the defined term “Owner Contracts” in its entirety and replacing it with the following:

““Owner Contracts” means:

 

  (1)

the Construction Agreement relating to the Marine Works to be entered into between Owner and TBD;

 

  (2)

the Construction Agreement relating to the Storm Surge Wall to be entered into between Owner and TBD;

 

  (3)

the LTS PO;

 

  (4)

the PIS PO;

 

1


(Execution Version)

 

  (5)

the LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 1) dated as of June 22, 2023 between CB&I Storage Tank Solutions LLC and Owner;

 

  (6)

the PTS PO;

 

  (7)

the Pipeline and Gas Gate Station PO;

 

  (8)

the BOG PO;

 

  (9)

the ACC PO;

 

  (10)

the Loading Arms PO;

 

  (11)

the Loading Pumps PO;

 

  (12)

the Cement PO;

 

  (13)

the Aggregates PO; and

 

  (14)

the Concrete Batch Plants PO.”

 

  (b)

Article 1 of the Agreement is hereby amended by inserting the following new defined terms in alphabetical order:

““Cement PO” means the purchase order contract for cement, concrete, and other consumables to be entered into by Owner.”

““Aggregates PO” means the purchase order contract for aggregate, riprap, and other consumables to be entered into by Owner.”

““Concrete Batch Plants PO” means the purchase order contract for concrete batch plants to be entered into by Owner.”

 

  (c)

Exhibit A, Section 4.8, sub-section 29) c) i. is amended by appending the following:

“For the avoidance of doubt, the following materials will be supplied by Owner:

 

   

cement for soil stabilization;

 

   

aggregate, gravel and lime for site preparation; and

 

   

ready-mix concrete.”

For the avoidance of doubt, the foregoing shall have no impact on the requirements set forth in Section 15.3.4. and as defined in Exhibit R to the Contract.

 

2


(Execution Version)

 

Price:

 

The Parties have agreed to reduce the Target Price by the amount of [***].
Initial Target Price:    [***]
Current Target Price:    [***]
Value of Change Order:    [***]
Adjusted Target Price as a result of this Change Order:    [***]

Deliverable Schedule:

This Change Order is not valid, except as otherwise provided in the Agreement, until fully executed by Contractor and Owner.

[Signatures on the following page.]

 

3


(Execution Version)

 

IN WITNESS WHEREOF, the Parties have caused this Change Order to be executed by their duly authorized representatives as of the date and year first above written.

 

Venture Global CP2 LNG, LLC    Worley Field Services Inc.
By: /s/ Keith Larson                   By: /s/ Amanda Knost               
Name: Keith Larson    Name: Amanda Knost
Title: General Counsel and Secretary    Title: President, US Gulf Coast

 

4

Exhibit 10.26

(Execution version)

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER

 

February 23, 2024    Change Order No. 3
    Reference: Soil Stabilization and Site
    Preparation De-scope
  

 Change Order Request No. SCO-0010

 Rev 2

Venture Global CP2 LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware (“Owner”), and Worley Field Services Inc., a corporation duly organized and validly existing under the laws of the State of Texas (“Contractor”), hereby agree to the following change to that certain Engineering, Procurement and Construction Agreement, dated as of May 12, 2023, by and between Owner and Contractor (as amended, supplemented or otherwise modified, the “Agreement”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order is considered an amendment to the Agreement. Except to the extent specifically described in this Change Order, the changes set forth herein do not relieve Contractor of its responsibilities set forth in the Agreement.

Provided that this Change Order is executed by both Parties, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the changes described herein, and shall be deemed to compensate Contractor fully for such effects, unless otherwise provided in the detailed description below.

Changes:

The Agreement is hereby modified with the revisions set forth below:

 

  (a)

Article 1 of the Agreement is hereby amended by deleting the defined term “Owner Contracts” in its entirety and replacing it with the following:

““Owner Contracts” means:

 

  (1)

the Construction Agreement relating to the Marine Works to be entered into between Owner and TBD;

 

  (2)

the Construction Agreement relating to the Storm Surge Wall to be entered into between Owner and TBD;

 

  (3)

the LTS PO;

 

  (4)

the PIS PO;

 

1


(Execution version)

 

  (5)

the LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 1) dated as of June 22, 2023 between CB&I Storage Tank Solutions LLC and Owner;

 

  (6)

the PTS PO;

 

  (7)

the Pipeline and Gas Gate Station PO;

 

  (8)

the BOG PO;

 

  (9)

the ACC PO;

 

  (10)

the Loading Arms PO;

 

  (11)

the Loading Pumps PO;

 

  (12)

the Cement PO;

 

  (13)

the Aggregates PO;

 

  (14)

the Concrete Batch Plants PO;

 

  (15)

the Site Preparation PO(s); and

 

  (16)

the Soil Stabilization PO(s).”

 

  (b)

Article 1 of the Agreement is hereby amended by inserting the following new defined terms in alphabetical order:

““Site Preparation PO means the purchase order contract to be entered into by Owner for clearing, grubbing, grading, pond excavation, pond grading, and filling to increase the ground elevation and to raise the site elevation as per the recommendations in project Geotechnical Report.”

““Soil Stabilization PO” means the purchase order contract to be entered into by Owner for soil stabilization.”

 

  (c)

Exhibit A, Section 2.1, sub-section 1) is hereby deleted in its entirety and replaced by:

“1) The Work includes all goods and services required for the design, engineering, procurement, expediting, transportation, management, construction, equipment preservation, installation, pre-commissioning, commissioning, start up and testing of the Facility, excluding the Owner Scope of Work.”

 

  (d)

Exhibit A, Section 3, sub-section 3.8 3) bb) is deleted in its entirety and the word “bb) [Reserved]” is inserted in its place.

 

2


(Execution version)

 

  (e)

Exhibit A, Section 4, sub-section 4.8 14) a) is deleted in its entirety and the following is inserted in its place:

“14) Site Preparation

 

  a)

Contractor shall provide a detailed plan for site clearing and filling to rough and final grade elevations, including the logistics, and stockpiling areas. Borrow areas of sufficient fill quantities of acceptable qualities are to be identified by Contractor.”

 

  (f)

Exhibit A, Section 4, sub-section 4.8 36) a) and b) are deleted in their entirety and the following is inserted in their place:

 

  “a)

Contractor shall accept the Job Site in the state it is provided.

 

  b)

Contractor shall implement measures to control all surface run-off drainage management for water sedimentation and evacuation. Excess or un-usable soils shall be removed from the Job Site only upon receipt of Owner prior written approval. Preparation of the Job Site and transport of quarried construction Materials shall be carried out in an environmentally acceptable manner.”

For the avoidance of doubt, the foregoing shall have no impact on the requirements set forth in Section 15.3.4. and as defined in Exhibit R to the Contract.

Price:

The Parties have agreed to reduce the Target Price by the amount of [***].

 

Initial Target Price:   [***]
Current Target Price:   [***]
Value of Change Order:   [***]
Adjusted Target Price as a result of this Change Order:   [***]

Deliverable Schedule:

This Change Order shall have no impact on the Project Schedule or Applicable Deadlines.

*******

This Change Order is not valid, except as otherwise provided in the Agreement, until fully executed by Contractor and Owner.

[Signatures on the following page.]

 

3


(Execution version)

 

IN WITNESS WHEREOF, the Parties have caused this Change Order to be executed by their duly authorized representatives as of the date and year first above written.

 

Venture Global CP2 LNG, LLC   Worley Field Services Inc.
By: /s/ Keith Larson                By: /s/ Amanda Knost             
Name: Keith Larson   Name: Amanda Knost
Title: General Counsel and Secretary   Title: President, US Gulf Coast

 

4

Exhibit 10.27

(Execution version)

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER

 

March 14, 2024    Change Order No. 4
   Reference: Exhibit W
   Change Order Request No. SCO-0001
   Rev 4

Venture Global CP2 LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware (“Owner”), and Worley Field Services Inc., a corporation duly organized and validly existing under the laws of the State of Texas (“Contractor”), hereby agree to the following change to that certain Engineering, Procurement and Construction Agreement, dated as of May 12, 2023, by and between Owner and Contractor (as amended, supplemented or otherwise modified, the “Agreement”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, agreed upon by the Parties pursuant to Article 12 of the Agreement, is considered an amendment to the Agreement. Except to the extent specifically described in this Change Order, the changes set forth herein do not relieve Contractor of its responsibilities set forth in the Agreement.

Provided that this Change Order is executed by both Parties, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the changes described herein, and shall be deemed to compensate Contractor fully for such effects, unless otherwise provided in the detailed description below.

Changes:

The Agreement is hereby modified with the revisions set forth below:

 

  (1)

Exhibit A, Section 4, sub-section 4.1 is hereby amended by inserting a new item 3) immediately following item 2):

“3) Contractor shall provide all necessary services related to the engineering, procurement, supply, transportation, logistics and installation of pre-cast piles (PCP) in lieu of displacement cast-in-place piles (DCIP).”

 

  (2)

Exhibit W (Open Cost Items) to the Agreement is hereby deleted in its entirety and the form of Exhibit W attached hereto as Attachment A shall be inserted in its place.

For the avoidance of doubt, the foregoing shall have no impact on the requirements set forth in Section 15.3.4. and as defined in Exhibit R to the Agreement.


(Execution version)

 

Price:  
Initial Target Price:   [***]
Current Target Price:   [***]
Value of Change Order:   [***]
Adjusted Target Price as a result of this Change Order:   [***]

Deliverable Schedule:

This Change Order shall have no impact on the Project Schedule or Applicable Deadlines.

This Change Order constitutes compensation in full for Contractor for performance of the changes set forth herein as described in Clause 1 to this Change Order.

This Change Order is not valid, except as otherwise provided in the Agreement, until fully executed by Contractor and Owner.

[Signatures on the following page.]


(Execution version)

 

IN WITNESS WHEREOF, the Parties have caused this Change Order to be executed by their duly authorized representatives as of the date and year first above written.

 

Venture Global CP2 LNG, LLC    Worley Field Services Inc.
By: /s/ Keith Larson                   By: /s/ Amanda Knost               
Name: Keith Larson    Name: Amanda Knost
Title: General Counsel and Secretary    Title: President, US Gulf Coast


(Execution version)

 

Attachment A

EXHIBIT W

OPEN COST ITEMS

[Omitted]

Exhibit 10.28

(Execution version)

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER

 

April 1, 2024       Change Order No. 5
      Reference: Construction Dewatering
      Outfall – Temporary Drainage System
      Change Order Request No. SCO-0005

Venture Global CP2 LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware (“Owner”), and Worley Field Services Inc., a corporation duly organized and validly existing under the laws of the State of Texas (“Contractor”) hereby agree to the following change to that certain Engineering, Procurement and Construction Agreement, dated as of May 12, 2023, by and between Owner and Contractor (as amended, supplemented or otherwise modified, the “Agreement”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, agreed upon by the Parties pursuant to Article 12 of the Agreement, is considered an amendment to the Agreement. Except to the extent specifically described in this Change Order, the changes set forth herein do not relieve Contractor of its responsibilities set forth in the Agreement.

Provided that this Change Order is executed by both Parties, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the changes described herein, and shall be deemed to compensate Contractor fully for such effects, unless otherwise provided in the detailed description below.

Changes:

The Agreement is hereby modified with the revisions set forth below:

 

  (1)

Exhibit A, Section 4, sub-section 4.4 item 24) a) iv) is hereby deleted in its entirety and replaced with the following:

“iv) Contractor shall provide all necessary services related to the Design and Build of the temporary drainage system in accordance with drawing C2-000000-PIP-SKT-WOR- 00002-001 Rev 1 and permanent drainage system to protect the plant against environmental conditions as per the conditions provided in the Basis of Design and philosophies. The plant shall be protected by storm surge wall concept;”

 

  (2)

Exhibit A is hereby amended by incorporating a new Attachment 3 (Temporary Site Drainage Drawing C2-000000-PIP-SKT-WOR-00002-001 Rev 1), attached hereto as Annex 1 to this change order.


(Execution version)

 

For the avoidance of doubt, the foregoing shall have no impact on the requirements set forth in Section 15.3.4. and as defined in Exhibit R to the Agreement.

 

Price:     

Initial Target Price:

  

[***]

Current Target Price:

  

[***]

Value of Change Order:

  

[***]

Adjusted Target Price as a result of this Change Order:

  

[***]

Deliverable Schedule:

This Change Order shall have no impact on the Project Schedule or Applicable Deadlines.

This Change Order constitutes compensation in full for Contractor for performance of the changes set forth herein as described in Clause 1 and Clause 2 to this Change Order.

This Change Order is not valid, except as otherwise provided in the Agreement, until fully executed by Contractor and Owner.

[Signatures on the following page.]


(Execution version)

 

IN WITNESS WHEREOF, the Parties have caused this Change Order to be executed by their duly authorized representatives as of the date and year first above written.

 

Venture Global CP2 LNG, LLC     Worley Field Services Inc.
By: /s/ Keith Larson                    By: /s/ Amanda Knost               
Name: Keith Larson     Name: Amanda Knost
Title: General Counsel and Secretary     Title: President, US Gulf Coast


(Execution version)

 

Annex 1

ATTACHMENT 3 (TEMPORARY SITE DRAINAGE)

Drawing No. C2-000000-PIP-SKT-WOR-00002-001 Rev 1

[Omitted]

Exhibit 10.29

AMENDMENT NO. 1

TO

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

THIS AMENDMENT NO. 1 TO ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this “Amendment No. 1”), dated as of May 10, 2024 (the “Amendment No. 1 Effective Date”), is entered into by and between Venture Global CP2 LNG, LLC, a Delaware limited liability company (“Owner”), and Worley Field Services Inc. a Texas Corporation (“Contractor”). Contractor and Owner are sometimes referred to herein individually as a “Party” and collectively as the “Parties.”

WHEREAS, Owner and Contractor are parties to that certain Engineering, Procurement and Construction Agreement dated as of May 12, 2023, and

WHEREAS, pursuant to Section 41.8 of the Agreement, Owner and Contractor desire to amend the Agreement as set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants and provisions herein contained, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby covenant and agree as follows:

1. Amendments.

 

  (a)

Exhibit C to the Agreement is deleted in its entirety and replaced with the document attached as Attachment A to this Amendment No. 1.

 

  (b)

Attachments C 1.1, C 1.3, and C 3.0 within Exhibit C shall be deemed effective as of October 1, 2023, for billing purposes. All other components of Exhibit C attached hereto as Attachment A shall be deemed effective as of the Amendment No. 1 Effective Date.

2. Benefits. This Amendment No. 1 shall inure to the benefit of and be binding upon the Parties and their respective successors and permitted assigns. Except with respect to the rights of successors and permitted assigns as provided in the Agreement, including any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders), nothing express or implied in this Amendment No. 1 is intended to confer upon any person, other than the Parties and their respective successors and assigns, any rights, remedies, obligations or liabilities under or by reason of this Amendment No. 1.

3. Effect of Amendment. Except as specifically set forth herein, the Agreement, as amended by this Amendment No. 1, remains in full force and effect in accordance with its terms.

4. No Oral Modifications. No oral or written modification, amendment or supplement of this Amendment No. 1 by any officer, agent or employee of Contractor or Owner, either before or after execution of this Amendment No. 1, shall be of any force or effect unless such modification, amendment, or supplement is in writing and is signed by both Parties.

5. Governing Law. This Amendment No. 1 shall in all respects be governed by, and construed in accordance with the laws of the State of New York without regard to principles of conflicts of laws.

 

1


6. Counterparts. This Amendment No. 1 may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute one and the same instrument. A signed copy of this Amendment No. 1 transmitted by facsimile or email shall be treated as an original and shall be binding against the Party whose signature appears on such copy.

[Signature page follows.]

 

2


IN WITNESS WHEREOF, the Parties have caused this Amendment No. 1 to be executed by their duly authorized representatives as of the Amendment No. 1 Effective Date.

 

Venture Global CP2 LNG, LLC     Worley Field Services Inc.
By: /s/ Keith Larson                    By: /s/ Amanda Knost               
Name: Keith Larson     Name: Amanda Knost
Title: General Counsel & Secretary     Title: President, US Gulf Coast

 

3


Attachment A

(Exhibit C – Contractor Rates attached)

[Omitted]

 

4

Exhibit 10.30

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

AMENDMENT NO. 2 TO

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

THIS AMENDMENT NO. 2 TO ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT (this Amendment No. 2), dated as of May 22, 2024 (the Amendment No. 2 Effective Date”), is entered into by and between Venture Global CP2 LNG, LLC, a Delaware limited liability company (“Owner”), and Worley Field Services, Inc. a Texas corporation (“Contractor”). Contractor and Owner are sometimes referred to herein individually as a Party and collectively as the Parties.

WHEREAS, Owner and Contractor are parties to that certain Engineering, Procurement and Construction Agreement dated as of May 12, 2023 (as amended, the Agreement’); and

WHEREAS, pursuant to Section 41.8 of the Agreement, Owner and Contractor desire to amend the Agreement as set forth herein.

NOW, THEREFORE, in consideration of the mutual covenants and provisions herein contained, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby covenant and agree as follows:

 

  1.

Amendments.

 

  (a)

The Agreement shall be amended by deleting the last sentence of Section 26.1.1 in its entirety and replaced with the sentence as set forth below:

“Contractor shall remain responsible for: (i) uninsured losses and deductible amounts under the policies to be provided by Contractor; (ii) the first [***] required to be provided by Owner pursuant to Section 26.3.l(e): and (iii) losses arising due to Contractor’s or its Subcontractor’s gross negligence or willful misconduct of Senior Supervisory Personnel under the policies to be provided by Owner until the Facility Substantial Completion Date, and Owner shall become responsible for such losses and deductibles occurring thereafter.”

 

  (b)

Section 26.2.1(g) of the Agreement is deleted in its entirety and noted as “[Reserved].”

 

  (c)

The following new Section 26.3.l(e) shall be inserted after Section 26.3.l(d) of the Agreement:

“(e) Pollution Liability Insurance, which shall include Contractor and Subcontractors of all tiers as insureds on a primary and non-contributory basis and include a waiver of subrogation in favor of such insureds. Coverage shall be provided on an occurrence basis (except for mold/fungi coverage which

 

1


may be on claims made basis). Minimum limits of coverage shall be at least [***] per claim and [***] in the annual aggregate, and coverage shall include liability to third parties for bodily injury, property damage, remediation, and clean-up costs arising from pollution conditions or events created by an insured, or an exacerbation by an insured of conditions on, at, or under the Job Site and/or from transportation and disposal of such pollutants. Such policy shall provide for completed operations extension or extended reporting period maintained for ten (10) years after Final Completion, or acceptance of the final payment for the Work, or to the applicable statute of repose, whichever is less.”

 

  (d)

The Agreement shall be amended by deleting the first sentence of Section 26.2.1 in its entirety and replaced with the sentence as set forth below:

“26.2.1 Except for the Construction and Erection All Risk insurance required to be provided by Owner pursuant to Section 26.3.1(a), the Commercial General Liability insurance required to be provided by Owner pursuant to Section 26.3.1(b), and the Pollution Liability Insurance required to be provided by Owner pursuant to Section 26.3.l(e), Contractor shall obtain and maintain in full force and effect, and shall require, as applicable, Subcontractors to procure and maintain in full force and effect, the following insurance:”

2. Benefits. This Amendment No. 2 shall inure to the benefit of and be binding upon the Parties and their respective successors and permitted assigns. Except with respect to the rights of successors and permitted assigns as provided in the Agreement, including any Person who purchases, leases or takes a security interest in an undivided interest in the Facility (including the Lenders), nothing express or implied in this Amendment No. 2 is intended to confer upon any person, other than the Parties and their respective successors and assigns, any rights, remedies, obligations or liabilities under or by reason of this Amendment No. 2.

3. Effect of Amendment. Except as specifically set forth herein, the Agreement, as amended by this Amendment No. 2, remains in full force and effect in accordance with its terms.

4. No Oral Modifications. No oral or written modification, amendment or supplement of this Amendment No. 2 by any officer, agent or employee of Contractor or Owner, either before or after execution of this Amendment No. 2, shall be of any force or effect unless such modification, amendment, or supplement is in writing and is signed by both Parties.

5. Governing Law. This Amendment No. 2 shall in all respects be governed by and construed in accordance with the laws of the State of New York without regard to principles of conflicts of laws.

6. Counterparts. This Amendment No. 2 may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute one and the same instrument. A signed copy of this Amendment No. 2 transmitted by facsimile or email shall be treated as an original and shall be binding against the Party whose signature appears on such copy.

 

2


IN WITNESS WHEREOF, the Parties have caused this Amendment No. 2 to be executed by their duly authorized representatives as of the Amendment No. 2 Effective Date.

 

Venture Global CP2 LNG, LLC     Worley Field Services Inc.
By: /s/ Keith Larson                    By: /s/ Amanda Knost               
Name: Keith Larson     Name: Amanda Knost
Title: General Counsel & Secretary     Title: President, US Gulf Coast

 

3

Exhibit 10.31

(Execution version)

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER

 

June 17, 2024    Change Order No. 6 Rev. 1
     Reference: Pollution Liability Insurance
     De-scope and Job Site Security Services
     De-scope

Venture Global CP2 LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware (“Owner”), and Worley Field Services Inc., a corporation duly organized and validly existing under the laws of the State of Texas (“Contractor”), hereby agree to the following change to that certain Engineering, Procurement and Construction Agreement, dated as of May 12, 2023, by and between Owner and Contractor (as amended, supplemented or otherwise modified, the “Agreement”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, agreed upon by the Parties pursuant to Article 12 of the Agreement, is considered an amendment to the Agreement. Except to the extent specifically described in this Change Order, the changes set forth herein do not relieve Contractor of its responsibilities set forth in the Agreement.

Provided that this Change Order, as revised, is executed by both Parties, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the changes described herein, and shall be deemed to compensate Contractor fully for such effects, unless otherwise provided in the detailed description below.

Changes:

The Agreement is hereby modified with the revisions set forth below:

 

  (1)

Article 1 “Owner Contracts” of the Agreement is hereby amended by inserting a new item “(17)” immediately following item “(16)”:

“(17) the Job Site Security Services MSA.”

 

  (2)

Article 1 of the Agreement is hereby amended by inserting the following new defined terms in alphabetical order:

““Job Site Security Services MSA” means the Job Site security services Master Services Agreement dated as of April 20, 2023 between Stratigos Dynamics, Inc. and Owner.”

 

  (3)

Section 3.7 of the Agreement is hereby amended by:

 

  (a)

by deleting sub-Section 3.7.9 in its entirety and replacing it with the following:

“3.7.9 obtain and maintain the insurance set forth in Section 26.3; and”


(Execution version)

 

  (b)

by inserting a new sub-Section 3.7.10 immediately following sub-Section 3.7.9:

“3.7.10 provide and pay for the Job Site security services.”

 

  (4)

The Parties agree to a reduction to the Target Price relating to the Pollution Liability Insurance coverage in accordance with Amendment No. 2 to the Agreement.

For the avoidance of doubt, the foregoing shall have no impact on the requirements set forth in Section 15.3.4. and as defined in Exhibit R to the Agreement.

Price:

The Parties have agreed to reduce the Target Price by the amount of [***].

 

Initial Target Price:    [***]
Current Target Price:    [***]
Value of Change Order:    [***]
Adjusted Target Price as a result of this Change Order:    [***]

Deliverable Schedule:

This Change Order shall have no impact on the Project Schedule or Applicable Deadlines.

********

This Change Order is not valid, except as otherwise provided in the Agreement, until fully executed by Contractor and Owner.

[Signatures on the following page.]


(Execution version)

 

IN WITNESS WHEREOF, the Parties have caused this Change Order to be executed by their duly authorized representatives as of the date and year first above written.

 

Venture Global CP2 LNG, LLC     Worley Field Services Inc.
By: /s/ Keith Larson                    By: /s/ Amanda Knost               
Name: Keith Larson     Name: Amanda Knost
Title: General Counsel and Secretary     Title: President, US Gulf Coast

Exhibit 10.32

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

FOURTH AMENDED AND RESTATED LETTER OF AGREEMENT

THIS FOURTH AMENDED AND RESTATED LETTER OF AGREEMENT (this “Agreement”), made as of April 7, 2023 (the “Effective Date”), is entered into by and between VENTURE GLOBAL LNG, INC., a Delaware corporation (“VGLNG”) and BAKER HUGHES ENERGY SERVICES LLC (f/k/a GE Oil & Gas, LLC), a Delaware limited liability company (“BH”). VGLNG and BH are sometimes referred to herein individually as a “Party” and collectively as the “Parties.”

RECITALS

WHEREAS, VGLNG, through its subsidiaries, is developing and/or constructing certain liquefied natural gas (“LNG”) export facilities within the United States of America, including the LNG export facility currently being constructed by Venture Global Calcasieu Pass, LLC (“VG Calcasieu Pass”) in Cameron Parish, Louisiana (the “Calcasieu Pass Project”), the LNG export facility currently being constructed by Venture Global Plaquemines LNG, LLC (“VG Plaquemines”) in Plaquemines Parish, Louisiana (the “Plaquemines LNG Project”), and the LNG export facility currently being developed by Venture Global CP2 LNG, LLC (“VG CP2 LNG”) in Cameron Parish, Louisiana (the “CP2 LNG Project”);

WHEREAS, BH and its affiliates (a) design, engineer, fabricate and manufacture certain natural gas liquefaction equipment, specifically natural gas liquefaction equipment consisting of liquefaction trains (each, a “Liquefaction Train”), with each Liquefaction Train consisting of one (1) six hundred twenty-six thousandth (0.626) million metric tonnes of LNG per annum (“MTPA”) liquefaction unit with associated electric-driven motorcompressor package (including auxiliaries), cold box, surge vessel and common e-house, all as further described in Appendix C that is included in Exhibit A, which is attached hereto and incorporated by reference herein, and (b) supply a nominally rated 611 MW [***] gas turbine combined cycle power island, which includes a gas insulated switchgear, and associated controls, auxiliaries and other equipment, the high-voltage to medium-voltage power distribution system in between the power island and the liquefaction system (each, a “Power Island System”), all as further described in Appendix C that is included in Exhibit B, which is attached hereto and incorporated by reference herein (the “Standard Configuration”) or an alternative configuration of power island equipment, which may include one or more [***] or [***] gas turbines to meet Project power demand in excess of available utility-supplied power (if any) (an “Alternative Configuration”), that may be selected by a Purchaser (as defined below);

WHEREAS, VGLNG, BH and VG Calcasieu Pass entered into that certain Letter of Agreement, dated as of July 13, 2016, as amended by Amendment No. 1 to Letter of Agreement, dated as of May 19, 2017, as further modified by a Letter Agreement, dated as of March 23, 2018, as amended by Amendment No. 2 to Letter of Agreement, dated as of July 30, 2018, as amended by Amendment No. 3 to Letter of Agreement, dated as of August 31, 2018, as amended by Amendment No. 4 to Letter of Agreement, dated as of September 13, 2018, as amended by Amendment No. 5 to Letter of Agreement, dated as of September 21, 2018, and as amended by Amendment No. 6 to Letter of Agreement, dated as of September 24, 2018 (as amended, restated or otherwise modified, the “Original Letter of Agreement”);

WHEREAS, VGLNG and BH entered into that certain Amended and Restated Letter of Agreement, dated as of September 25, 2018, as amended by Amendment No. 1 to Amended and Restated Letter of Agreement, dated as of June 24, 2019, Amendment No. 2 to Amended and Restated Letter of Agreement, dated as of October 31, 2019, Amendment No. 3 to Amended and Restated Letter of Agreement, dated as of January 24, 2020, Amendment No. 4 to Amended and Restated Letter of Agreement, dated as of February 12, 2020, Amendment No. 5 to Amended and Restated Letter of Agreement, dated as of February 27, 2020, Amendment No. 6 to Amended and Restated Letter of Agreement, dated as of March 27, 2020, Amendment No. 7 to Amended and Restated Letter of Agreement, dated as of April 30, 2020, Amendment No. 8 to


Amended and Restated Letter of Agreement, dated as of May 29, 2020, Amendment No. 9 to Amended and Restated Letter of Agreement, dated as of June 12, 2020, Amendment No. 10 to Amended and Restated Letter of Agreement, dated as of June 29, 2020, Amendment No. 11 to Amended and Restated Letter of Agreement, dated as of July 31, 2020, Amendment No. 12 to Amended and Restated Letter of Agreement, dated as of August 31, 2020, Amendment No. 13 to Amended and Restated Letter of Agreement, dated as of September 15, 2020, Amendment No. 14 to Amended and Restated Letter of Agreement, dated as of October 15, 2020, Amendment No. 15 to Amended and Restated Letter of Agreement, dated as of October 30, 2020, Amendment No. 16 to Amended and Restated Letter of Agreement, dated as of November 16, 2020, Amendment No. 17 to Amended and Restated Letter of Agreement, dated as of December 4, 2020, Amendment No. 18 to Amended and Restated Letter of Agreement, dated as of December 18, 2020, Amendment No. 19 to Amended and Restated Letter of Agreement, dated as of January 22, 2021, Amendment No. 20 to Amended and Restated Letter of Agreement, dated as of February 5, 2021, and Amendment No. 21 to Amended and Restated Letter of Agreement, dated as of February 19, 2021 (as amended, the “First Amended and Restated Letter of Agreement”), which replaced and superseded the Original Letter of Agreement in its entirety;

WHEREAS, VGLNG and BH entered into that certain Second Amended and Restated Letter of Agreement, dated as of February 26, 2021, as amended by Amendment No. 1 to Second Amended and Restated Letter of Agreement, dated as of January 19, 2022, and Amendment No. 2 to Second Amended and Restated Letter of Agreement, dated as of June 23, 2022, Amendment No. 3 to Amended and Restated Letter of Agreement, dated as of July 6, 2022, Amendment No. 4 to Amended and Restated Letter of Agreement, dated as of July 21, 2022, and Amendment No. 5 to Amended and Restated Letter of Agreement, dated as of July 29, 2022 (as amended, the “Second Amended and Restated Letter of Agreement”), which replaced and superseded the First Amended and Restated Letter of Agreement in its entirety;

WHEREAS, VGLNG and BH entered into that certain Third Amended and Restated Letter of Agreement, dated as of September 26, 2022 (as amended, the “Third Amended and Restated Letter of Agreement”), which replaced and superseded the Second Amended and Restated Letter of Agreement in its entirety;

WHEREAS, on September 25, 2018, VG Calcasieu Pass and BH entered into that certain (a) Purchase Order for the Sale of Liquefaction Train System (as amended, the “First LTS Purchase Order”) and (b) Purchase Order for the Sale of Power Island System (as amended, the “First PIS Purchase Order”);

WHEREAS, on February 26, 2021, VG Plaquemines and BH entered into that certain (a) Purchase Order for the Sale of Liquefaction Train System, as amended and restated by that certain Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System dated January 19, 2022 (as amended, the “Second LTS Purchase Order”) and (b) Purchase Order for the Sale of Power Island System (as amended, the “Second PIS Purchase Order”);

WHEREAS, on February 3, 2022, VG Plaquemines and BH entered into that certain Purchase Order for the Sale of Power Island System (as amended, the “Third PIS Purchase Order”) for the purchase of a power island system, comprised of “Tranche A” and “Tranche B” (as such terms are defined in the Third PIS Purchase Order);

WHEREAS, August 5, 2022, VG Plaquemines and BH entered into that certain Purchase Order for the Sale of Liquefaction Train System (as amended, the “Third LTS Purchase Order”);

 

2


WHEREAS, VGLNG, through its subsidiaries, may elect to expand the natural gas liquefaction capacity of the Calcasieu Pass Project, the Plaquemines LNG Project and/or the CP2 LNG Project (or any phase thereof) and/or develop additional natural gas liquefaction projects within or outside the United States of America, through the procurement of additional Liquefaction Train Systems and Power Island Systems (each, a “Project”);

WHEREAS, VGLNG and BH desire to reserve or caused to be reserved dedicated manufacturing capacity for VGLNG and to agree on the price, schedule and other terms for the sale and delivery during the time periods described herein of (a) up to [***] Liquefaction Trains manufactured by BH or its affiliates capable of producing in the aggregate no less than [***] MTPA and (b) up to [***] Power Island Systems in a Standard Configuration or an Alternative Configuration, which VGLNG or its designated affiliate, subsidiary, contractor or designee (each, a “Purchaser”) confirm selection of such equipment for the Projects subject to the terms and conditions set forth herein;

WHEREAS, pursuant to the Unconditional Performance Obligations (as defined in each Purchase Order (as defined below) attached hereto) applicable to the Liquefaction Train System and the Power Island System, a Seller (as defined below) will, subject to the terms and conditions of the Purchase Orders, provide Purchaser with a process system performance guarantee with production and efficiency standards for each Project;

WHEREAS, BH and its affiliates will continue to expand the Manufacturing Facilities located in [***] and will increase the number of manufacturing bays in the areas labeled A and B in Exhibit F to [***];

WHEREAS, VGLNG and BH desire to reserve or caused to be reserved additional manufacturing capacity, such that VGLNG, through its subsidiaries, may have the right to purchase additional Liquefaction Trains, on and subject to the terms and conditions set forth herein;

WHEREAS, BH, or where permitted herein the applicable affiliate or subsidiary of BH that is sufficiently qualified and capable of performing the relevant LTS Purchase Order or PIS Purchase Order, (BH or such affiliate or subsidiary, as applicable, a “Seller”), intends to supply to each Purchaser Seller equipment for deployment and installation worldwide, on and subject to the terms and conditions set forth herein; and

WHEREAS, VGLNG and BH desire to replace and supersede the Third Amended and Restated Letter of Agreement in its entirety, as set forth in this Agreement.

NOW, THEREFORE, in consideration of the promises and the agreements in this Agreement, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties, intending to be legally bound, agree as follows:

1. MANUFACTURING CAPACITY

1.1 Reservation of Dedicated Manufacturing Capacity for Liquefaction Train Systems and Power Island Systems.

(a) Liquefaction Train Systems.

i. In consideration of the obligations in this Agreement, BH shall cause to be reserved for VGLNG dedicated manufacturing capacity at BH’s affiliated manufacturing facilities located in [***] or [***] (collectively, the “Manufacturing Facilities”), such that [***] sets of [***] Liquefaction Trains, each capable of producing in the aggregate no less than eleven and

 

3


twenty-seven hundredths (11.27) MTPA (each such set, a “Liquefaction Train System”), shall, except as provided in Section 1.1(a)(xii), be manufactured at (x) the Manufacturing Facilities or (y) solely in the event that the Manufacturing Facilities are at the relevant time engaged in manufacturing Liquefaction Trains for one or more Purchasers and do not have sufficient capacity to manufacture all or part of a subsequent set of Liquefaction Trains, another, mutually agreed BH affiliated manufacturing facility located in [***], and delivered to each applicable Purchaser in accordance with the delivery schedule set forth in Section 2.2(a).

ii. The foregoing obligation to reserve manufacturing capacity at the Manufacturing Facilities shall expire, if at all, on [***] (the “Fourth LTS Order End Date”) if a Purchaser has not executed a definitive purchase agreement substantially in the form attached hereto as Exhibit A, which is incorporated by reference herein, for one (1) Liquefaction Train System (a “LTS Purchase Order”, and such LTS Purchase Order, the “Fourth LTS Purchase Order”) on or before the Fourth LTS Order End Date.

iii. If a Purchaser has executed the Fourth LTS Purchase Order on or before the Fourth LTS Order End Date, the foregoing obligation to reserve manufacturing capacity at the Manufacturing Facilities shall continue with respect to the [***] remaining Liquefaction Train Systems, and shall expire, if at all, on [***] (the “Fifth LTS Order End Date”) if a Purchaser has not executed an additional LTS Purchase Order for one (1) Liquefaction Train System (the “Fifth LTS Purchase Order”), on or before the Fifth LTS Order End Date.

iv. If a Purchaser has executed the Fifth LTS Purchase Order on or before the Fifth LTS Order End Date, the foregoing obligation to reserve manufacturing capacity at the Manufacturing Facilities shall continue with respect to the [***] remaining Liquefaction Train Systems, and shall expire, if at all, on [***] (the “Sixth LTS Order End Date”) if a Purchaser has not executed an additional LTS Purchase Order for one (1) Liquefaction Train System (the “Sixth LTS Purchase Order”) on or before the Sixth LTS Order End Date.

v. If a Purchaser has executed the Sixth LTS Purchase Order on or before the Sixth LTS Order End Date, the foregoing obligation to reserve manufacturing capacity at the Manufacturing Facilities shall continue with respect to the [***] remaining Liquefaction Train Systems, and shall expire, if at all, on [***] (the “Seventh LTS Order End Date”) if a Purchaser has not executed an additional LTS Purchase Order for one (1) Liquefaction Train System (the “Seventh LTS Purchase Order”), on or before the Seventh LTS Order End Date.

vi. If a Purchaser has executed the Seventh LTS Purchase Order on or before the Seventh LTS Order End Date, the foregoing obligation to reserve manufacturing capacity at the Manufacturing Facilities shall continue with respect to the [***] remaining Liquefaction Train Systems, and shall expire, if at all, on [***] (the “Eighth LTS Order End Date”) if a Purchaser has not executed an additional LTS Purchase Order for one (1) Liquefaction Train System (the “Eighth LTS Purchase Order”) on or before the Eighth LTS Order End Date.

vii. If a Purchaser has executed the Eighth LTS Purchase Order on or before the Eighth LTS Order End Date, the foregoing obligation to reserve manufacturing capacity at the Manufacturing Facilities shall continue with respect to the [***] remaining Liquefaction Train Systems, and shall expire, if at all, on [***] (the “Ninth LTS Order End Date”) if a Purchaser has not executed an additional LTS Purchase Order for one (1) Liquefaction Train System (the “Ninth LTS Purchase Order”), on or before the Ninth LTS Order End Date.

 

4


viii. If a Purchaser has executed the Ninth LTS Purchase Order on or before the Ninth LTS Order End Date, the foregoing obligation to reserve manufacturing capacity at the Manufacturing 4 Facilities shall continue with respect to the [***] remaining Liquefaction Train Systems, and shall expire, if at all, on [***] (the “Tenth LTS Order End Date”) if a Purchaser has not executed an additional LTS Purchase Order for one (1) Liquefaction Train System (the “Tenth LTS Purchase Order”) on or before the Tenth LTS Order End Date.

ix. If a Purchaser has executed the Tenth LTS Purchase Order on or before the Tenth LTS Order End Date, the foregoing obligation to reserve manufacturing capacity at the Manufacturing Facilities shall continue with respect to the [***] remaining Liquefaction Train Systems, and shall expire, if at all, on [***] (the “Eleventh LTS Order End Date”) if a Purchaser has not executed an additional LTS Purchase Order for one (1) Liquefaction Train System (the “Eleventh LTS Purchase Order”) on or before the Eleventh LTS Order End Date.

x. If a Purchaser has executed the Eleventh LTS Purchase Order on or before the Eleventh LTS Order End Date, the foregoing obligation to reserve manufacturing capacity at the Manufacturing Facilities shall continue with respect to the [***] remaining Liquefaction Train Systems, and shall expire, if at all, on [***] (the “Twelfth LTS Order End Date”) if a Purchaser has not executed an additional LTS Purchase Order for one (1) Liquefaction Train System (the “Twelfth LTS Purchase Order”) on or before the Twelfth LTS Order End Date.

xi. If a Purchaser has executed the Twelfth LTS Purchase Order on or before the Twelfth LTS Order End Date, the foregoing obligation to reserve manufacturing capacity at the Manufacturing Facilities shall continue with respect to [***] remaining Liquefaction Train System and shall expire, if at all, on [***] (the “Final LTS Order End Date” and, together with the Seventh LTS Order End Date, the Eighth LTS Order End Date, the Ninth LTS Order End Date, the Tenth LTS Order End Date, the Eleventh LTS Order End Date and the Twelfth LTS Order End Date, the “Expansion LTS Order End Dates” and, together with the Fourth LTS Order End Date, the Fifth LTS Order End Date and the Sixth LTS Order End Date, the “LTS Order End Dates”) if a Purchaser has not executed an additional LTS Purchase Order for one (1) Liquefaction Train System (the “Final LTS Purchase Order”, and together with the Seventh LTS Purchase Order, the Eighth LTS Purchase Order, the Ninth LTS Purchase Order, the Tenth LTS Purchase Order, the Eleventh LTS Purchase Order and the Twelfth LTS Purchase Order, the “Expansion LTS Purchase Orders”), on or before the Final LTS Order End Date.

xii. BH shall, with respect to each Expansion LTS Purchase Order, be permitted to, at any time during the period commencing twelve (12) months prior to the Expansion LTS Order End Date relating to such Expansion LTS Purchase Order and ending six (6) months prior to such Expansion LTS Order End Date, notify VGLNG in writing of its request to utilize one or more manufacturing facilities (including subcontracted third party facilities) other than one of the Manufacturing Facilities for the manufacture of the Liquefaction Train System under such Expansion LTS Purchase Order, such notice to include (x) a revised, reasonably detailed proposal for the relevant LTS Purchase Order with specific pricing and delivery schedule for the relevant Liquefaction Train System and (y) written confirmation from BH that such manufacturing facility(ies) are subject to quality assurance and quality control programs consistent with the quality assurance and control programs of BH. VGLNG shall, within sixty (60) days of its receipt of BH’s notice, consider for acceptance BH’s request, such acceptance not to be unreasonably withheld or delayed. The Parties agree to, or to cause their applicable affiliates to, negotiate in good faith with respect to such request, including in respect of any revised terms and conditions of any LTS Purchase Order that are necessary to restore the benefit of the bargain to VGLNG in terms of cost (including any modifications to the foreign exchange adjustments set forth in Exhibit E and adjustments for commodity prices and labor costs set forth in Exhibit D based upon the location(s) of the relevant manufacturing facilities and corresponding changes in labor and commodities indices), quality and schedule for delivery, but that it shall not be unreasonable for VGLNG to withhold its acceptance of any such request if Seller’s utilization of one

 

5


or more manufacturing facilities other than one of the Manufacturing Facilities for the manufacture of the relevant Liquefaction Train System could reasonably be expected to have a material adverse impact on the cost (including any modifications to the foreign exchange adjustments set forth in Exhibit E and adjustments for commodity prices and labor costs set forth in Exhibit D based upon location(s) of the relevant manufacturing facilities and corresponding changes in labor and commodities indices), quality or schedule for delivery of such Liquefaction Train System (as compared to Seller’s utilization of one of the Manufacturing Facilities for the manufacture of such Liquefaction Train System in accordance with the terms of this Agreement). If VGLNG rejects BH’s request in writing or otherwise has not accepted BH’s request (including if VGLNG fails to respond in writing to BH’s request) within such sixty (60) day period, then (w) in the event that VGLNG has not accepted BH’s request, VGLNG shall be deemed to have rejected BH’s request, (x) neither BH nor any other applicable Seller shall have an obligation to reserve manufacturing capacity for such Liquefaction Train System, (y) VGLNG, and its subsidiaries and affiliates shall no longer be obligated to utilize BH for the manufacturing of such Liquefaction Train System and (z) Section 2.3(a)(v) and Section 2.3(a)(vi) shall no longer be applicable with respect to such Liquefaction Train System.

xiii. BH shall, with respect to each Expansion LTS Purchase Order, be permitted to, at any time during the period commencing twelve (12) months prior to the Expansion LTS Order End Date relating to such Expansion LTS Purchase Order and ending six (6) months prior to such Expansion LTS Order End Date, notify VGLNG in writing that a material and adverse change in market conditions, including any changes in Liquefaction Train System design and/or scope necessary to meet design codes and/or standards in a location that is outside of the United States of America, applicable to such Expansion LTS Purchase Order, including a material increase in material, labor and subcontractor costs that is not otherwise recoverable under the terms of this Agreement or such Expansion LTS Purchase Order, has occurred and as a direct result thereof Seller’s performance under such Expansion LTS Purchase Order has been rendered commercially impracticable, such notice to include a reasonably detailed description of the changes in market conditions and the basis for BH’s determination of such commercial impracticability. VGLNG shall, within sixty (60) days of its receipt of BH’s notice, consider for acceptance BH’s request, such acceptance not to be unreasonably withheld or delayed. The Parties or their applicable affiliates shall promptly meet and discuss in good faith such changes in market conditions and consider equitable adjustments to the relevant Expansion LTS Purchase Order that are necessary to restore the Parties’ or their applicable affiliates’ relative economic positions. If within ninety (90) days following VGLNG’s receipt of BH’s notice, VGLNG and Seller have not agreed upon mutually acceptable equitable adjustments to the relevant Expansion LTS Purchase Order that are necessary to restore their relative economic positions, then (w) VGLNG shall be deemed to have rejected BH’s request, (x) neither BH nor the applicable Seller shall have an obligation to reserve manufacturing capacity for such Liquefaction Train System, (y) VGLNG, and its subsidiaries and affiliates shall no longer be obligated to utilize BH for the manufacturing of such Liquefaction Train System and (z) Section 2.3(a)(v) and Section 2.3(a)(vi) shall no longer be applicable with respect to such Liquefaction Train System.

xiv. Each of BH and VGLNG acknowledges and agrees that a Purchaser shall be entitled to purchase a Liquefaction Train System pursuant to an LTS Purchase Order for installation in the United States of America or in a jurisdiction outside of the United States of America. In the event of any Liquefaction Train System to be installed in a jurisdiction outside of the United States of America, BH shall notify VGLNG of the Seller that will supply such Liquefaction Train System, and such Seller will become a party to this Agreement with respect to the applicable LTS Purchase Order pursuant to a mutually agreeable accession agreement. Notwithstanding anything to the contrary set forth in this Agreement (a) VGLNG shall notify BH of its intention to purchase a Liquefaction Train System pursuant to an LTS Purchase Order for installation outside of the United States of America at any time prior to the date that is twelve (12) months prior to such LTS Order End Date, and (b) the Purchaser and Seller shall cooperate with each other and discuss amendments and/or updates to the Liquefaction Train System Scope of Supply

 

6


and configuration, the delivery terms and schedule, the LTS Purchase Price, the LTS Transportation Costs and the form of LTS Purchase Order that may be necessary and appropriate to reflect the specific site conditions, legal requirements, design codes and standards, natural gas composition or other identifiable and measurable factors adversely affecting the performance of the Liquefaction Train System in the relevant non-U.S. jurisdiction. If the Purchaser and Seller have not agreed upon a mutually acceptable Purchase Order for the Liquefaction Train System Scope of Supply, the delivery terms and schedule, the LTS Purchase Price, the LTS Transportation Costs and the form of LTS Purchase Order pursuant to the immediately preceding sentence by the relevant LTS Order End Date, then, without affecting BH’s other obligations under this Agreement: (x) neither BH nor any other applicable Seller shall have an obligation to reserve or caused to be reserved manufacturing capacity for such Liquefaction Train System; (y) VGLNG and its subsidiaries and affiliates shall no longer be obligated to utilize BH or any other Seller for the manufacturing of such Liquefaction Train System; and (z) Section 2.3(a)(v) and Section 2.3(a)(vi) shall no longer be applicable with respect to such Liquefaction Train System.

xv. If VGLNG, through its subsidiaries, decides to construct a Project comprised of thirty-six (36) Liquefaction Trains in respect of which a single Purchaser will enter two (2) LTS Purchase Orders, then each of the two (2) LTS Purchase Orders may be for a reconfigured Liquefaction Train System comprised of (i) eighteen (18) or more Liquefaction Trains, in respect of the first LTS Purchase Order for such Project, and (ii) the remaining number of Liquefaction Trains in respect of the second LTS Purchase Order for such Project. In such event references to a “Liquefaction Train System” in clauses (ii) through (xi) of this Section 1.1(a) shall be treated as a reference to such reconfigured Liquefaction Train System.

(b) Power Island Systems.

i. In consideration of the obligations in this Agreement, BH shall cause to be reserved for VGLNG dedicated manufacturing capacity at a manufacturing facility of General Electric Company or one or more of its subsidiaries (acting as a subcontractor of the Seller), such that [***] Power Island Systems shall be manufactured for the Seller by General Electric Company or one or more of its subsidiaries and delivered to each applicable Purchaser in accordance with the delivery schedule set forth in Section 2.2(b).

ii. The foregoing reservation of manufacturing capacity shall expire, if at all, on [***] (the “Fourth PIS Order End Date”) if a Purchaser has not executed a definitive purchase agreement in the form attached hereto as Exhibit B for one (1) Power Island System, which at Purchaser’s election may be comprised of Tranche A and Tranche B (a “PIS Purchase Order”) (such PIS Purchase Order, the “Fourth PIS Purchase Order”) on or before the Fourth PIS Order End Date.

iii. If a Purchaser has executed the Fourth PIS Purchase Order on or before the Fourth PIS Order End Date, the foregoing reservation of manufacturing capacity shall continue with respect to the [***] remaining Power Island Systems and shall expire, if at all, on [***] (the “Fifth PIS Order End Date”) if a Purchaser has not executed an additional PIS Purchase Order for one (1) Power Island System, which at Purchaser’s election may be comprised of Tranche A and Tranche B (the “Fifth PIS Purchase Order”) on or before the Fifth PIS Order End Date.

iv. If a Purchaser has executed the Fifth PIS Purchase Order on or before the Fifth PIS Order End Date, the foregoing reservation of manufacturing capacity shall continue with respect to the [***] remaining Power Island Systems and shall expire, if at all, on [***] (the “Sixth PIS Order End Date”) if a Purchaser has not executed an additional PIS Purchase Order for one (1) Power Island System, which at Purchaser’s election may be comprised of Tranche A and Tranche B (the “Sixth PIS Purchase Order”) on or before the Sixth PIS Order End Date.

 

7


v. If a Purchaser has executed the Sixth PIS Purchase Order on or before the Sixth PIS Order End Date, the foregoing reservation of manufacturing capacity shall continue with respect to the [***] remaining Power Island Systems and shall expire, if at all, on [***] (the “Seventh PIS Order End Date”) if a Purchaser has not executed an additional PIS Purchase Order for one (1) Power Island System, which at Purchaser’s election may be comprised of Tranche A and Tranche B (the “Seventh PIS Purchase Order”) on or before the Seventh PIS Order End Date.

vi. If a Purchaser has executed the Seventh PIS Purchase Order on or before the Seventh PIS Order End Date, the foregoing reservation of manufacturing capacity shall continue with respect to the [***] remaining Power Island Systems and shall expire, if at all, on [***] (the “Eighth PIS Order End Date”) if a Purchaser has not executed an additional PIS Purchase Order for one (1) Power Island System, which at Purchaser’s election may be comprised of Tranche A and Tranche B (the “Eighth PIS Purchase Order”) on or before the Eighth PIS Order End Date.

vii. If a Purchaser has executed the Eighth PIS Purchase Order on or before the Eighth PIS Order End Date, the foregoing reservation of manufacturing capacity shall continue with respect to the [***] remaining Power Island Systems and shall expire, if at all, on [***] (the “Ninth PIS Order End Date”) if a Purchaser has not executed an additional PIS Purchase Order for one (1) Power Island System, which at Purchaser’s election may be comprised of Tranche A and Tranche B (the “Ninth PIS Purchase Order”) on or before the Ninth PIS Order End Date.

viii. If a Purchaser has executed the Ninth PIS Purchase Order on or before the Ninth PIS Order End Date, the foregoing reservation of manufacturing capacity shall continue with respect to the [***] remaining Power Island Systems and shall expire, if at all, on [***] (the “Tenth PIS Order End Date”) if a Purchaser has not executed an additional PIS Purchase Order for one (1) Power Island System, which at Purchaser’s election may be comprised of Tranche A and Tranche B (the “Tenth PIS Purchase Order”) on or before the Tenth PIS Order End Date.

ix. If a Purchaser has executed the Tenth PIS Purchase Order on or before the Tenth PIS Order End Date, the foregoing reservation of manufacturing capacity shall continue with respect to the [***] remaining Power Island Systems and shall expire, if at all, on [***] (the “Eleventh PIS Order End Date”) if a Purchaser has not executed an additional PIS Purchase Order for one (1) Power Island System, which at Purchaser’s election may be comprised of Tranche A and Tranche B (the “Eleventh PIS Purchase Order”) on or before the Eleventh PIS Order End Date.

x. If a Purchaser has executed the Eleventh PIS Purchase Order on or before the Eleventh PIS Order End Date, the foregoing reservation of manufacturing capacity shall continue with respect to the [***] remaining Power Island Systems and shall expire, if at all, on [***] (the “Twelfth PIS Order End Date”) if a Purchaser has not executed an additional PIS Purchase Order for one (1) Power Island System, which at Purchaser’s election may be comprised of Tranche A and Tranche B (the “Twelfth PIS Purchase Order”) on or before the Twelfth PIS Order End Date.

xi. If a Purchaser has executed the Twelfth PIS Purchase Order on or before the Twelfth PIS Order End Date, the foregoing reservation of manufacturing capacity shall continue with respect to [***] remaining Power Island System and shall expire, if at all, on [***] (the “Final PIS Order End Date”, and together with the Seventh PIS Order End Date, the Eighth PIS Order End Date, the Ninth PIS Order End Date, the Tenth PIS Order End Date, the Eleventh PIS Order End Date and the Twelfth PIS Order End Date, the “Expansion PIS Order End Dates”, and, together with the Fourth PIS Order End Date, the Fifth PIS Order End Date and the Sixth PIS Order End Date, the “PIS Order End Dates”) if a Purchaser has not executed an additional PIS Purchase Order for one (1) Power Island System, which at Purchaser’s election may be comprised of Tranche A and Tranche B (the “Final PIS Purchase Order” and, together with the Seventh PIS Purchase Order, the Eighth PIS Purchase Order, the Ninth PIS Purchase Order, the Tenth PIS Purchase Order, the Eleventh PIS Purchase Order and the Twelfth PIS Purchase Order, the “Expansion PIS Purchase Orders”) on or before the Final PIS Order End Date.

 

8


xii. BH shall, with respect to each Expansion PIS Purchase Order, be permitted to, at any time during the period commencing twelve (12) months prior to the Expansion PIS Order End Date relating to such Expansion PIS Purchase Order and ending six (6) months prior to such Expansion PIS Order End Date, notify VGLNG in writing that a material and adverse change in market conditions, including any changes in Power Island System design and/or scope necessary to meet design codes and/or standards in a location outside of the United States of America applicable to such Expansion PIS Purchase Order, including a material increase in material, labor and subcontractor costs that is not otherwise recoverable under the terms of this Agreement or such Expansion PIS Purchase Order, has occurred and as a direct result thereof Seller’s performance under such Expansion PIS Purchase Order has been rendered commercially impracticable, such notice to include a reasonably detailed description of the changes in market conditions and the basis for BH’s determination of such commercial impracticability. VGLNG shall, within sixty (60) days of its receipt of BH’s notice, consider for acceptance BH’s request, such acceptance not to be unreasonably withheld or delayed. The Parties or their applicable affiliates shall promptly meet and discuss in good faith such changes in market conditions and consider equitable adjustments to the relevant Expansion PIS Purchase Order that are necessary to restore their relative economic positions. If within ninety (90) days following VGLNG’s receipt of BH’s notice, VGLNG and Seller have not agreed upon mutually acceptable equitable adjustments to the relevant Expansion PIS Purchase Order that are necessary to restore their relative economic positions, then (w) VGLNG shall be deemed to have rejected BH’s request, (x) neither BH nor the applicable Seller shall have an obligation to reserve or caused to be reserved manufacturing capacity for such Power Island System, (y) VGLNG, and its subsidiaries and affiliates shall no longer be obligated to utilize BH for the supply of such Power Island System and (z) Section 2.3(b)(iv) shall no longer be applicable with respect to such Power Island System.

xiii. Each of BH and VGLNG acknowledges and agrees that a Purchaser shall be entitled to purchase a Power Island System pursuant to a PIS Purchase Order for installation in the United States of America or in a jurisdiction outside of the United States of America. In the event of any Power Island System to be installed in a jurisdiction outside of the United States of America, BH shall notify VGLNG of the Seller that will supply such Power Island System and such Seller will become a party to this Agreement with respect to the applicable PIS Purchase Order pursuant to a mutually agreeable accession agreement. Notwithstanding anything to the contrary set forth in this Agreement, (a) VGLNG shall notify BH of its intention to purchase the Power Island System pursuant to a PIS Purchase Order for installation outside of the United States of America any time prior to the date that is twelve (12) months prior to such PIS Order End Date, and (b) the Purchaser and Seller shall cooperate with each other and discuss amendments and/or updates to the Power Island System Scope of Supply and configuration, the PIS Purchase Price, the delivery schedule, the PIS Transportation Costs and the form of PIS Purchase Order that may be necessary and appropriate to reflect the specific site conditions, legal requirements, design codes and standards, natural gas composition or other identifiable and measurable factors adversely affecting the performance of the Power Island System in the relevant non-U.S. jurisdiction. If the Purchaser and Seller have not agreed upon a mutually acceptable Purchase Order for the Power Island System Scope of Supply and configuration, the delivery terms and schedule, the PIS Purchase Price, the PIS Transportation Costs and the form of PIS Purchase Order by the relevant PIS Order End Date, then, without affecting BH’s other obligations under this Agreement: (x) neither BH nor any other applicable Seller shall have an obligation to cause to be reserved manufacturing capacity for such Power Island System; (y) VGLNG and its subsidiaries and affiliates shall no longer be obligated to utilize BH or any other Seller for the manufacturing supply of such Power Island System and (z) Section 2.3(b)(iv) shall no longer be applicable with respect to such Power Island System.

 

9


1.2 Original Letter of Agreement, First Amended and Restated Letter of Agreement, Second Amended and Restated Letter of Agreement and Third Amended and Restated Letter of Agreement. The Parties hereby acknowledge and agree that:

(a) the Original Letter of Agreement was superseded in its entirety by the First Amended and Restated Letter of Agreement and is no longer of any force and effect as of September 25, 2018;

(b) the First Amended and Restated Letter of Agreement was superseded in its entirety by the Second Amended and Restated Letter of Agreement and is no longer of any force and effect as of February 26, 2021;

(c) the Second Amended and Restated Letter of Agreement is hereby superseded in its entirety by this Agreement and is no longer of any force and effect as of September 26, 2022;

(d) the Third Amended and Restated Letter of Agreement is hereby superseded in its entirety by this Agreement and is no longer of any force and effect as of the Effective Date;

(e) VGLNG shall retain all rights, title and interest to any work product or other deliverables produced by BH under the Original Letter of Agreement or the Letter of Intent dated as of December 10, 2015 between VG Calcasieu Pass and BH (the “Letter of Intent”), other than work product and other deliverables produced by BH under the Letter of Intent for which BH was to be compensated under invoice number [***] in the amount of [***] that was issued by BH on April 19, 2016 under the Letter of Intent; and

(f) there are no outstanding claims by either Party or any amounts owed by one Party to the other Party under the Original Letter of Agreement, the First Amended and Restated Letter of Agreement, the Second Amended and Restated Letter of Agreement and the Third Amended and Restated Letter of Agreement.

(g) [***]

1.3 Manufacturing Capacity for additional Liquefaction Trains

In addition to the existing reservation of capacity set forth herein, BH agrees to reserve additional manufacturing capacity at the Manufacturing Facilities located in [***], built or repurposed to be capable of manufacturing the Liquefaction Train Systems described in Section 1.1(a), for a period starting on the Effective Date and ending on the Final LTS Order End Date or [***], whichever occurs earlier (the “Additional Reservation Period”) for the purchase of additional Liquefaction Trains on the following terms set forth below:

 

  (a)

At any time during the Additional Reservation Period, VGLNG or the applicable Purchaser will have the right to purchase additional Liquefaction Train(s) under one or more purchase order (“LT Purchase Order(s)”) that shall be negotiated in good faith by BH and VGLNG or

 

10


  the applicable Purchaser in accordance with the following: (i) each LT Purchase Order shall be for up to one LTS Block (as defined below) and there must be [***] bays available at the Manufacturing Facilities located at [***] built or repurposed to be capable of manufacturing such LTS Block; and (ii) the issuance of such LT Purchase Order does not conflict or impact Seller’s obligations under an LTS Purchase Order or the reservation of manufacturing capacity for the Liquefaction Train Systems described in Section 1.1(a) of this Agreement. Seller is obligated to demonstrate to Buyer if there are supplier conflicts that require an extended delivery time or other consideration by the Buyer.

 

  (b)

VGLNG shall notify in writing to BH of its intent to purchase a LTS Block, in which case no later than ninety (90) days from the date of VGLNG’s notice (or such other time as mutually agreed by the Parties in writing), a Purchaser or VGLNG and BH shall negotiate in good faith and execute a definitive LT Purchase Order authorizing Seller to proceed with full scope of work under such agreement. The LT Purchase Order shall be mutually agreed by Seller and the applicable Purchaser and shall be substantially in the form of Exhibit A to this Agreement with required revisions, including changes to the Scope of Supply, the delivery terms and schedule, the purchase price (which shall be calculated based on the terms set forth in Section 1.3(c) subject to reasonable market-based adjustments), Transportation Costs, warranties and performance guarantees; provided that (i) delivery terms under LT Purchase Orders will be DDP (INCOTERMS 2020) the delivery point reasonably identified by VGLNG or the applicable Purchaser, subject to delivery delay liquidated damages and early completion bonus being assessed upon shipping of the applicable Liquefaction Trains from the Manufacturing Facilities located in [***] and issuance and acceptance of a “Ready for Shipment/ Mechanical Inspection Certificate”, and (ii) the delivery date will be [***] from the effective date of such LT Purchase Order. VGLNG and BH acknowledge and agree neither VGLNG, nor any Purchaser, shall be obligated to purchase or pay for, and neither BH nor any Seller shall be obligated to sell or supply any of the Additional Liquefaction Train, unless or until a definitive LT Purchase Order is executed by the applicable Purchaser and the applicable Seller. For the avoidance of doubt, failure to enter into a LT Purchase Order shall have no impact on BH’s obligations under any LTS Purchase Orders, including with respect to delivery dates set forth in any such LTS Purchase Order.

 

  (c)

The purchase price for each additional Liquefaction Train under an LT Purchase Order shall be calculated as follows:

 

    i.

If the LT Purchase Order is for the purchase of at least one (1) and not more than two (2) Liquefaction Trains, then the purchase price for each such additional Liquefaction Train will be an amount equal to [***];

 

   ii.

If the LT Purchase Order is for the purchase of at least three (3) and not more than six (6) Liquefaction Trains, then the purchase price for each such additional Liquefaction Train will be an amount equal to [***]; and

 

  iii.

If the LT Purchase Order is for the purchase of at least seven (7) Liquefaction Trains, then the purchase price for each such additional Liquefaction Train will be an amount equal to [***].

 

11


2. PURCHASE AND DELIVERY OF LIQUEFACTION TRAIN SYSTEMS AND POWER ISLAND SYSTEMS

2.1 Purchase of the Liquefaction Train Systems and Power Island Systems.

(a) Liquefaction Train Systems.

i. One or more Purchasers intends to purchase from a Seller up to [***] Liquefaction Train Systems (in addition to the Liquefaction Train Systems purchased pursuant to the First LTS Purchase Order, the Second LTS Purchase Order and the Third LTS Purchase Order) capable of producing no less than [***] MTPA pursuant to one (1) or more LTS Purchase Orders, subject to the terms and conditions of this Agreement.

ii. BH and VGLNG intend that the applicable Seller and the applicable Purchaser shall, upon the election by VGLNG, execute one (1) or more LTS Purchase Orders for: (i) the fourth Liquefaction Train System on or before the Fourth LTS Order End Date; (ii) the fifth Liquefaction Train System on or before the Fifth LTS Order End Date; (iii) the sixth Liquefaction Train System on or before the Sixth LTS Order End Date; (iv) the seventh Liquefaction Train System on or before the Seventh LTS Order End Date; (v) the eighth Liquefaction Train System on or before the Eighth LTS Order End Date; (vi) the ninth Liquefaction Train System on or before the Ninth LTS Order End Date; (vii) the tenth Liquefaction Train System on or before the Tenth LTS Order End Date; (viii) the eleventh Liquefaction Train System on or before the Eleventh LTS Order End Date; (ix) the twelfth Liquefaction Train System on or before the Twelfth LTS Order End Date; and (x) the thirteenth Liquefaction Train System on or before the Final LTS Order End Date, in each case, for delivery of such Liquefaction Train Systems to the relevant Project designated by Purchaser in accordance with the relevant LTS Purchase Order and the delivery schedule set forth in Section 2.2(a). Notwithstanding Section 2.1(a)(i), VGLNG and BH acknowledge and agree that, subject to Section 2.3(a)(v), neither VGLNG, nor any Purchaser, shall be obligated to purchase or pay for and, without prejudice to its obligations under Section 1, neither BH nor any Seller shall be obligated to sell or supply any of the Liquefaction Train Systems, unless or until a definitive LTS Purchase Order is executed by the applicable Purchaser and the applicable Seller.

(b) Power Island Systems.

i. One or more Purchasers intends to purchase from the applicable Sellers up to [***] Power Island Systems (in addition to Power Island Systems purchased pursuant to the First PIS Purchase Order, the Second PIS Purchase Order and the Third PIS Purchase Order) pursuant to one (1) or more PIS Purchase Orders, subject to the terms and conditions of this Agreement.

ii. BH and VGLNG intend the applicable Seller and the applicable Purchaser shall, upon the election by VGLNG, execute one (1) or more PIS Purchase Orders for: (i) the fourth Power Island System on or before the Fourth PIS Order End Date; (ii) the fifth Power Island System on or before the Fifth PIS Order End Date; (iii) the sixth Power Island System on or before the Sixth PIS Order End Date; (iv) the seventh Power Island System on or before the Seventh PIS Order End Date; (v) the eighth Power Island System on or before the Eighth PIS Order End Date; (vi) the ninth Power Island System on or before the Ninth PIS Order End Date; (vii) the tenth Power Island System on or before the Tenth PIS Order End Date; (viii) the eleventh Power Island System on or before the Eleventh PIS Order End Date; (ix) the twelfth Power Island System on or before the Twelfth PIS Order End Date; and (x) the thirteenth Power Island System on or before the Final PIS Order End Date, in each case, for delivery of such Power Island Systems to the relevant Project designated by a Purchaser to a Seller in accordance with the relevant PIS Purchase Order and the delivery schedule set forth in Section 2.2(b) (in each case as adjusted for an Alternative Configuration). Notwithstanding Section 2.1(b)(i), VGLNG and BH acknowledge and agree that, subject to Section 2.3(b)(iv), neither VGLNG nor any Purchaser shall be obligated to purchase or pay for, and neither BH nor any Seller shall be obligated to sell or supply, any of the Power Island Systems unless or until a definitive PIS Purchase Order is executed by the applicable Purchaser and the applicable Seller.

 

12


2.2 Schedule for Delivery of the Liquefaction Train Systems and Power Island Systems.

(a) Liquefaction Train Systems.

i. The delivery schedule for the Liquefaction Trains assumes that a limited notice to proceed pursuant to Appendix A attached to Exhibit A of this Agreement (“LTS LNTP”) will be issued authorizing the scope of services included in such LTS LNTP with respect to the applicable LTS Purchase Order for a Liquefaction Train System no later than [***] prior to the issuance of the full notice to proceed authorizing the applicable Seller to proceed with the full scope of work under such LTS Purchase Order (“LTS FNTP”). If the LTS LNTP is issued less than [***] prior to the issuance of the LTS FNTP under a LTS Purchase Order, the delivery schedule for such LTS Purchase Order shall be extended day for day for each day the LTS LNTP was issued less than [***] prior to the issuance of the LTS FNTP. VGLNG and BH acknowledge and agree that the amounts payable with respect to the services performed under the LTS LNTP for a LTS Purchase Order, not including any amount that may be due in connection with a termination of the LTS Purchase Order, shall be payable in accordance with the payment schedule set forth in Appendix B to Exhibit A of this Agreement and shall not exceed [***] of the Contract Price. The scope of the applicable Seller’s services under the LTS LNTP is described in Appendix C that is included in Exhibit A, which is attached hereto and incorporated by reference herein.

ii. VGLNG and BH acknowledge that the Liquefaction Trains will be delivered when completed on a specific schedule that requires continuous and regular deliveries. While initial delivery dates may vary and are ultimately subject to the terms of the applicable LTS Purchase Order, the applicable Seller will deliver the Liquefaction Trains under such LTS Purchase Order as follows: (i) the first two (2) Liquefaction Trains under such LTS Purchase Order within [***] following the LTS FNTP date of such LTS Purchase Order; (ii) each subsequent set of two (2) Liquefaction Trains under such LTS Purchase Order will be delivered between [***] and [***] after the delivery date of the preceding set of two (2) Liquefaction Trains until the total quantity of Liquefaction Trains under such LTS Purchase Order is complete. The delivery schedule under each LTS Purchase Order shall ensure that at least [***] exist between the delivery date of the last two (2) Liquefaction Trains of an LTS Purchase Order and the delivery date of the first two (2) Liquefaction Trains of the subsequent LTS Purchase Order; provided however in the event that delivery dates under an LTS Purchase Order, as scheduled pursuant to the immediately preceding sentence, overlap with or occur prior to the date that is [***] after the delivery date of the last two (2) Liquefaction Trains under the preceding LTS Purchase Order, the Parties shall negotiate in good faith the delivery dates under such subsequent LTS Purchase Order.

iii. As applicable under an LTS Purchase Order, if Seller identifies specific supply chain constraints to any Major Component (as such term is defined in Section 3.2), e-houses and/or module steel structures in such LTS Purchase Order, Seller shall have the right to demonstrate those concerns to Buyer no later than thirty (30) days prior to expected date of issuance of such LTS Purchase Order, and Buyer and Seller shall reasonably negotiate in good faith the scope, schedule and amount to be paid under the LTS LNTP under such LTS Purchase Order.

iv. With respect to each LTS Purchase Order, BH and the applicable Purchaser shall negotiate in good faith adjustments to the structure and timing of payment of, without modification to the aggregate amount of, any bonus for early delivery described in clause 6.7 of Appendix A attached to Exhibit A of this Agreement.

 

13


(b) Power Island Systems.

i. The delivery schedule for the Power Island Systems assumes that a limited notice to proceed pursuant to Appendix A attached to Exhibit B of this Agreement (“PIS LNTP”) will be issued authorizing the scope of services included in such PIS LNTP with respect to the applicable PIS Purchase Order for a Liquefaction Train System no later than [***] prior to the issuance of the full notice to proceed authorizing the applicable Seller to proceed with the full scope of work under such PIS Purchase Order (“PIS FNTP”). If the PIS LNTP is issued less than [***] prior to the issuance of the PIS FNTP, the delivery schedule for the applicable PIS Purchase Order shall be extended day for day for each day the PIS LNTP was issued less than [***] prior to the issuance of the PIS FNTP. VGLNG and BH acknowledge and agree that the amounts payable with respect to the services performed under the PIS LNTP for a PIS Purchase Order, not including any amount that may be due in connection with a termination of the PIS Purchase Order, shall be payable in accordance with the payment schedule set forth in Appendix B to Exhibit B of this Agreement and shall not exceed [***]. The scope of the applicable Seller’s services under the PIS LNTP is described in Appendix C that is included in Exhibit B, which is attached hereto and incorporated by reference herein.

ii. While initial delivery dates may vary and are ultimately subject to the terms of the applicable PIS Purchase Order, the applicable Seller will deliver the Power Island Systems under such PIS Purchase Order as follows: (i) the first gas turbine and generator set under such PIS Purchase Order within [***] following the PIS FNTP date of such PIS Purchase Order; (ii) the second gas turbine generator set under such PIS Purchase Order within [***] following the PIS FNTP date of such PIS Purchase Order; (iii) the third gas turbine generator set under such PIS Purchase Order within [***] following the PIS FNTP date of such PIS Purchase Order; (iv) the fourth gas turbine generator set under such PIS Purchase Order within [***] following the PIS FNTP date of such PIS Purchase Order; (v) the final gas turbine generator set under such PIS Purchase Order within [ * * * ] following the PIS FNTP date of such PIS Purchase Order; (vi) the gas insulated switchgear under such PIS Purchase Order within [***] following the PIS FNTP date of such PIS Purchase Order; (vii) the first steam turbine generator set under such PIS Purchase Order within [***] following the PIS FNTP date of such PIS Purchase Order; (viii) the second steam turbine generator set under such PIS Purchase Order within [***] following the PIS FNTP date of such PIS Purchase Order; and (ix) the remaining equipment as defined in Appendix C of the applicable PIS Purchase Order; provided, however, that the delivery schedule for the Power Island Systems is subject to the PIS LNTP conditions set forth in Section 2.2(b)(i) and to adjustment as provided in the applicable PIS Purchase Order. In the event delivery dates for a Simple Cycle Component or Other Component (such terms are defined in the applicable PIS Purchase Orders) under a PIS Purchase Order overlap with or occur within [***] of the delivery date of the last equivalent Simple Cycle Component or Other Component under the preceding PIS Purchase Order, the parties shall negotiate in good faith the delivery dates under such subsequent PIS Purchase Order.

iii. As applicable under a PIS Purchase Order, if Seller identifies specific supply chain constraints to the Simple Cycle Components or Other Components in such PIS Purchase Order, Seller shall have the right to demonstrate those concerns to Buyer no later than thirty (30) days prior to expected date of issuance of the PIS Purchase Order, and Buyer and Seller shall reasonably negotiate in good faith the scope, schedule and amount to be paid under the PIS LNTP under such PIS Purchase Order.

iv. With respect to the Fourth PIS Purchase Order and each subsequent PIS Purchase Order, upon the request of VGLNG, the applicable Purchaser and the applicable Seller agree to negotiate in good faith the design, scope, delivery schedule and price of an Alternative Configuration to be supplied by the applicable Seller for all or part of the power demand in excess of utility-supplied power for the relevant Project, which Alternative Configuration shall be priced on non-discriminatory, market terms for such Alternative Configuration.

 

14


2.3 Purchase Price for the Liquefaction Train Systems and Power Island Systems.

(a) Liquefaction Train Systems.

i. The purchase price for each Liquefaction Train System (the “LTS Purchase Price”) shall be equal to the sum of: (1) [***]; and (2) [***].

ii. The applicable Seller shall deliver each Liquefaction Train DDP the marine offloading facility(ies) adjacent to the Project site as designated by Purchaser to Seller for the items to be delivered by barge (Incoterms 2010) and DDP the Project site for the items to be delivered by truck (Incoterms 2010), as specified in the relevant LTS Purchase Order (each, a “Delivery Point”). The items will be supplied to the relevant jurisdiction in which they will be installed, cleared through customs and duty-paid for use in that jurisdiction. The LTS Purchase Price shall not include any Liquefaction Train System duties and tariffs paid by the applicable Seller to deliver each Liquefaction Train in accordance with the preceding sentence (“LTS Duties”), and physical transportation costs, exclusive of insurance costs and taxes associated with physical transportation costs other than LTS Duties, for each such Liquefaction Train (“LTS Transportation Costs”). Purchaser shall reimburse the applicable Seller pursuant to the LTS Purchase Order requirements for all reasonable, documented out-of-pocket LTS Duties and LTS Transportation Costs incurred by the applicable Seller, plus a fixed fee of [***], for the applicable Seller’s management of the Liquefaction Train deliveries (divided proportionally based upon delivery of each Liquefaction Train and payable by Purchaser monthly). LTS Transportation Costs, inclusive of the fixed fee, shall, subject to the following two sentences, not exceed [***] in the aggregate; provided that the applicable Seller has made commercially reasonable efforts to obtain competitive transportation pricing terms and to minimize transportation costs. When the amount of LTS Transportation Costs forecast by Seller reaches [***] of the not to exceed amount of LTS Transportation Costs amount set forth above and Seller reasonably estimates that the aggregate Transportation Costs may exceed such not to exceed amount of LTS Transportation Costs, Seller shall notify the applicable Purchaser and provide an estimate of the remaining LTS Transportation Costs anticipated to complete the Liquefaction Train System deliveries under the applicable LTS Purchase Order. Purchaser will reasonably consider an adjustment to the not to exceed LTS Transportation Costs; provided that any such increase in the LTS Transportation Costs shall be mutually agreed in a change order to such LTS Purchase Order. At least [***] prior to the delivery of the first Liquefaction Train under a LTS Purchase Order, the applicable Seller shall provide to Purchaser for Purchaser’s review and approval a plan for the delivery of the Liquefaction Trains, in accordance with the delivery schedule, including the identity of the transportation vendors and the estimated LTS Transportation Costs for such LTS Purchase Order, such approval not to be unreasonably withheld, conditioned or delayed.

iii. The LTS Purchase Price for each LTS Purchase Order shall be firm and not subject to any adjustments, other than increases or decreases in the LTS Purchase Price resulting from (i) [***], (ii) [***], (iii) with respect to component (1) of such LTS Purchase Price for each LTS Purchase Order, by an additional amount based upon changes in labor and commodities indices in accordance with Exhibit D, which is attached hereto and incorporated by reference herein, (iv) a foreign exchange adjustment to component (1) of such LTS Purchase Price in accordance with Exhibit E, which is attached hereto and incorporated by reference herein, and (v) in the case of any Expansion LTS Purchase Order, any adjustments contemplated in Section 1.1(a)(ix), and (v) after the execution of such LTS Purchase Order, any adjustment pursuant to the terms and conditions of such LTS Purchase Order.

 

15


iv. The obligation for holding the price and delivery schedule for the Liquefaction Train Systems in accordance with this Agreement is subject to and contingent, (i) for the fourth Liquefaction Train System, on a Purchaser executing the Fourth LTS Purchase Order, and (ii) for each subsequent Liquefaction Train System, on Purchaser executing each of the LTS Purchase Orders after the Fourth LTS Purchase Order that relate to a Liquefaction Train System that precedes such subsequent Liquefaction Train System, in each case, within the timeframes detailed in Section 1.1(a).

v. Subject to Section 1.1(a)(ix), in exchange for BH performing all of its obligations under this Agreement and provided that no BH event of default has occurred and is continuing under this Agreement, if VGLNG, through its subsidiaries, commences construction of a Project that is intended to produce an amount of liquefied natural gas for off-take from such Project that has the design capacity of the Liquefaction Train System described in Appendix C to the LTS Purchase Order: (i) such Project shall utilize a Liquefaction Train System manufactured by BH, its affiliates or BH’s designee and VGLNG shall not, directly or through a subsidiary, affiliate, or other entity, utilize a Liquefaction Train System manufactured by an entity other than BH, its affiliates or BH’s designee for such Project, and (ii) if the project is in the United States of America, VGLNG shall cause such Project owner to specify such Liquefaction Train System manufactured by BH or its designee as part of the Federal Energy Regulatory Commission (“FERC”) filings for such Project. Upon receiving a written request by BH, VGLNG shall make available to BH, to the extent permissible to do so, copies of the FERC filings for any such Project evidencing inclusion of the Liquefaction Train System manufactured by BH as part of the FERC filings for such Project.

vi. In exchange for BH performing all of its obligations under this Agreement and provided that no BH event of default has occurred and is continuing under this Agreement, if VGLNG, through its subsidiaries, decides to construct a Project that is intended to produce an amount of liquefied natural gas for off-take from such Project that is less or more than [***] MTPA and that does not have the design capacity of the Liquefaction Train System described in Appendix C to the LTS Purchase Order, then the LTS Purchase Price will be adjusted as follows:

A. If the reconfigured Liquefaction Train System will be comprised of between [***] each (each such block, a “LTS Block”), then the purchase price for the reconfigured Liquefaction Train System under the applicable LTS Purchase Order will be equal to [***];

B. If the reconfigured Liquefaction Train System will be comprised of between [***], then the purchase price for the reconfigured Liquefaction Train System under the applicable LTS Purchase Order will be equal to [***]; and

C. If the reconfigured Liquefaction Train System will be comprised of [***], then the purchase price for the reconfigured Liquefaction Train System under the applicable LTS Purchase Order will be equal to [***].

 

16


In such a circumstance, (1) [***], and (2) if the project is in the United State of America, VGLNG shall cause such Project owner to specify [***]. Upon receiving a written request by BH, VGLNG shall make available to BH, to the extent permissible to do so, copies of the FERC filings for any such Project evidencing inclusion of the Liquefaction Train System manufactured by BH or its affiliate as part of the FERC filings for such Project.

vii. BH represents and warrants to VGLNG that Appendix C to the LTS Purchase Order (the “Liquefaction Train System Scope of Supply”) includes all of the necessary obligations that are required to be performed by the applicable Seller in order for each of the Liquefaction Train Systems to operate in accordance with the requirements of the LTS Purchase Order and satisfy the design codes, standards and the performance guarantees set forth in the LTS Purchase Order. Notwithstanding Section 2.3(a)(ii), BH and VGLNG acknowledge and agree that the Liquefaction Train System Scope of Supply describes the items for the Liquefaction Train System being provided in general, but not in complete detail. BH and VGLNG agree that any specific items not set forth in the Liquefaction Train System Scope of Supply, or any details or clarifications thereto, that are required in order to satisfy the requirements of the LTS Purchase Order or to satisfy the design codes, standards and the performance guarantees set forth therein, in each case, will not be considered changes to the Liquefaction Train System Scope of Supply, unless they are explicitly excluded from the Liquefaction Train System Scope of Supply, are changes to the basis of design directed by Purchaser or changes pursuant to the change order process of the LTS Purchase Order and [***]. The Parties acknowledge and agree that the Liquefaction Train System Scope of Supply contains certain single-line diagrams, pipe and instrumentation diagrams and other diagrams and drawings that will change as a Seller completes its engineering of the Liquefaction Train System and that any change to such diagrams and drawings, which are not the result of changes to the basis of design directed by Purchaser or changes made pursuant to the change order process of the LTS Purchase Order, will not be changes that will entitle either the applicable Purchaser or the applicable Seller to an increase in the LTS Purchase Price or an extension of the delivery schedule for the Liquefaction Train System under the LTS Purchase Order.

(b) Power Island Systems.

i. The purchase price for each Power Island System in a Standard Configuration (the “PIS Purchase Price”) under a PIS Purchase Order shall be [***]. VGLNG and the applicable Seller shall negotiate in good faith the pricing for an Alternative Configuration of the Power Island System in accordance with Section 2.2(b)(iii) if such Alternative Configuration is selected by a Purchaser. The applicable Seller shall deliver each Power Island System DDP to the applicable Delivery Point (Incoterms 2010). The PIS Purchase Price shall not include any Power Island System duties and tariffs paid by the applicable Seller to deliver each Power Island System in accordance with the preceding sentence (“PIS Duties”), and physical transportation costs, exclusive of insurance costs and taxes associated with physical transportation costs other than PIS Duties, for each such Power Island System (“PIS Transportation Costs”). The items will be supplied to the relevant jurisdiction in which they will be installed, cleared through customs and duty-paid for use in that jurisdiction. Purchaser shall reimburse the applicable Seller pursuant to the PIS Purchase Order requirements for all reasonable, documented out-of-pocket PIS Duties and PIS Transportation Costs incurred by the applicable Seller, plus a fixed fee of [***] for the applicable Seller’s management of the Power Island System deliveries. PIS Transportation Costs, inclusive of the fixed fee, shall, subject to the following two sentences, not exceed [***] in the aggregate, provided that the applicable Seller has made commercially reasonable efforts to obtain competitive transportation pricing terms and to minimize transportation costs. When the amount of PIS Transportation Costs forecast by Seller reaches [***] of the not to exceed amount of PIS Transportation Costs amount set forth above and Seller reasonably estimates that the aggregate PIS Transportation Costs may exceed such not to exceed amount

 

17


of PIS Transportation Costs, Seller shall notify the applicable Purchaser and provide an estimate of the remaining PIS Transportation Costs anticipated to complete the Power Island System deliveries under the applicable PIS Purchase Order. Purchaser will reasonably consider an adjustment to the not to exceed PIS Transportation Costs; provided that any such increase in the PIS Transportation Costs shall be mutually agreed in a change order to such PIS Purchase Order. At least [***] prior to the delivery of the first component under a PIS Purchase Order, the applicable Seller shall provide to Purchaser for Purchaser’s review and approval a plan for the delivery of the Power Island System, in accordance with the delivery schedule, including the identity of the transportation vendors and the estimated PIS Transportation Costs for such PIS Purchase Order, such approval not to be unreasonably withheld, conditioned or delayed.

ii. The PIS Purchase Price for each PIS Purchase Order shall be firm and not subject to any adjustments, other than increases or decreases in the PIS Purchase Price resulting from [***], (iii) by an additional amount based upon changes in labor and commodities indices in accordance with Exhibit D, (iv) a foreign exchange adjustment to such PIS Purchase Price in accordance with Exhibit E, (v) adjustments related to the selection of an Alternative Configuration and (vi) after the execution of the applicable PIS Purchase Order, an adjustment pursuant to the terms and conditions of such PIS Purchaser Order.

iii. The obligation for holding the price and delivery schedule for the Power Island Systems in accordance with this Agreement as the same may be adjusted for any Alternative Configuration, and is further subject to and contingent (i) for the fourth Power Island System, on a Purchaser executing the Fourth PIS Purchase Order and (ii) for each subsequent Power Island System, on Purchaser executing each of the PIS Purchase Orders after the Fourth LTS Purchase Order that relate to a Power Island System that precedes such subsequent Power Island System, in each case, within the timeframes detailed in Section 1.1(b).

iv. In exchange for BH performing all of its obligations under this Agreement and provided that no BH event of default has occurred and is continuing under this Agreement, if VGLNG, through its subsidiaries, purchases a Liquefaction Train System for a Project that has the design capacity of the Liquefaction Train System described in Appendix C to the LTS Purchase Order, [***]; however, if such Project does not have the design capacity of the Liquefaction Train System described in Appendix C to the LTS Purchase Order then [***].

v. BH represents and warrants to VGLNG that Appendix C to the PIS Purchase Order (the “Power Island System Scope of Supply”) includes all of the necessary obligations that are required to be performed by an applicable Seller in order for each of the Power Island Systems to operate in accordance with the requirements of the PIS Purchase Order and satisfy the design codes, standards and the performance guarantees set forth in the PIS Purchase Order. Notwithstanding Section 2.3(b)(ii), BH and VGLNG acknowledge and agree that the Power Island System Scope of Supply describes the items for the Power Island System being provided in general, but not in complete detail. BH and VGLNG agree that any specific items not set forth in the Power Island System Scope of Supply, or any details or clarifications thereto, that are required in order to satisfy the requirements of the PIS Purchase Order or to satisfy the design codes, standards and the performance guarantees set forth therein, in each case, will not be considered changes to the Power Island System Scope of Supply, unless they are explicitly excluded from the Power Island System Scope of Supply, or are changes to the basis of design as directed by Purchaser, or are changes pursuant to the change order requirements of the PIS Purchase Order and, both [***].

 

18


3. ADDITIONAL AGREEMENTS.

3.1 FEED Services. BH acknowledges that as the equipment supplier for the Projects, a Seller will be expected to enter into subcontracts (provided that such subcontracts have commercial, technical and other terms and conditions reasonably acceptable to and approved by the Seller) with certain contractors designated by VGLNG that will be parties to the FEED agreements and engineering, procurement and construction agreements for each Project (each, an “Owner Contractor”) related to the provision of FEED services for the Projects. In order to ensure coordination between the applicable Project owner and the Seller with respect to such subcontracts, BH, for itself and its affiliates and subsidiaries, shall not enter into any arrangement with any Owner Contractor that (a) is inconsistent with any of the terms and conditions contained in the Agreement or any LTS Purchase Order or PIS Purchase Order, or (b) in any way restricts or seeks to restrict VGLNG or the applicable Project owner’s selection of an Owner Contractor for a Project that will utilize the Liquefaction Trains or Power Island Systems, such as a transaction pursuant to which a Seller agrees with an Owner Contractor that Seller will not supply Liquefaction Trains or Power Island Systems to any purchaser that does not engage such Owner Contractor, in each case, without the prior written consent of VGLNG.

3.2 Major Components. In cases where the applicable Seller is not the manufacturer or the supplier of Major Components, BH acknowledges and agrees that VGLNG or the applicable Purchaser shall have the right to consent to and approve the supplier of each major component of equipment comprising the (a) Liquefaction Train Systems [***], (b) Power Island Systems [***], (c) pressure transmitters, flow transmitters, automated control or isolation valves greater than [***] and associated actuators for both the Liquefaction Train Systems and Power Island Systems (in the case of (a), (b), an (c), each, a “Major Component”). To assist VGLNG or the applicable Purchaser in the selection of Major Components, for each potential vendor or supplier of a Major Component the applicable Seller will provide VGLNG or the applicable Purchaser with access to: (1) the identity of the potential vendor or supplier; (2) the delivery and schedule terms for the Major Component; (3) in the case of the [***], the price negotiated by the applicable Seller for such Major Components; and (4) all technical and performance information for each Major Component requested by VGLNG or the applicable Purchaser. To the extent a Major Component supplier is changed based on a VGLNG or Purchaser directive and, as a result of such change in Major Component supplier, the applicable Seller incurs a documented incremental increase in the price of the Major Component or delay in the delivery of the Major Component that adversely affects the delivery schedule for the Liquefaction Trains or the Power Island Systems, the applicable Seller shall receive an equitable adjustment in the purchase price and delivery schedule for the applicable Liquefaction Train or Power Island System.

3.3 Field Services. BH acknowledges and agrees that, upon the election by VGLNG or the applicable Purchaser, in its discretion, BH or one or more of its affiliates and the applicable Project owner shall enter into a field services agreement for the provision of installation, commissioning, start-up, testing, operational training and operation and maintenance services (“Field Services Agreement”) for each Project, in substantially the form of the Field Services Agreement dated May 2, 2022 between VG Plaquemines and BH.

 

19


3.4 Long-term Service Agreement. BH acknowledges and agrees that, upon the election by VGLNG or the applicable Purchaser, in its discretion, BH or one or more of its affiliates and the applicable Project owner shall enter into a long-term service agreement (“Long-Term Service Agreement”) for the provision of for long-term maintenance services for the Liquefaction Train Systems and Power Island Systems contemplated herein, in substantially the form of the Long Term Services Agreement dated as of December 8, 2022 between VG Calcasieu Pass and BH.

3.5 Additional Power Generation. In the event that a Purchaser requires additional permanent power generation for a Project, VGLNG shall request, on behalf of such Purchaser, and BH shall provide a commercial quotation for the supply of additional power generation equipment by BH or a Seller. Upon Purchaser’s notice (in its sole discretion), Purchaser and Seller shall negotiate in good faith the inclusion of the supply of any such additional power generation equipment in the applicable PIS Purchase Order, including any special terms and conditions that may be required for such scope of supply; provided for the avoidance of doubt that the relevant Purchaser shall have no obligation to purchase such additional power generation from BH or a Seller.

3.6 Term. This Agreement shall become effective on the date of execution hereof by all of the Parties and shall continue in full force and effect until the earliest of: (i) the expiration of BH’s obligation to maintain manufacturing capacity pursuant to Section 1.1(a)(ii), Section 1.1(a)(iii), Section 1.1(a)(iv), Section 1.1(a)(v), Section 1.1(a)(vi), Section 1.1(a)(vii), Section 1.1(a)(viii), Section 1.1(a)(ix), Section 1.1(a)(x), Section 1.1(a)(xi), Section 1.1(b)(ii), Section 1.1(b)(iii), Section 1.1(b)(iv), Section 1.1(b)(v), Section 1.1(b)(vi), Section 1.1(b)(vii), Section 1.1(b)(viii), Section 1.1(b)(ix), Section 1.1(b)(x) and Section 1.1(b)(xi) of this Agreement; (ii) the execution by a Purchaser and the applicable Seller of the Final LTS Purchase Order and the Final PIS Purchase Order; (iii) the permanent cancellation and abandonment of all of the Projects for which a LTS Purchase Order or PIS Purchase Order has not been executed by a Purchaser and the applicable Seller, evidenced by the formal announcement of such cancellation and withdrawal of any pending FERC filings related to such Projects; and (iv) the written agreement of the Parties to terminate this Agreement.

3.7 Price and Performance Optimization. VGLNG and BH agree to reasonably cooperate and work together in good faith with the shared objective of using the experience, knowledge and data derived from the performance under this Agreement, the FEED agreements and any LTS Purchase Orders to optimize the project management services, engineering services, procurement, manufacturing and performance of each Liquefaction Train System in combination with the balance of plant of each Project (excluding BH improvements that are unrelated to and do not impact the performance, reliability or maintenance of the relevant Liquefaction Train System(s)) with the common goals of (x) increasing the operational performance of the Liquefaction Train Systems and (y) if possible and solely to the extent consistent with clause (x), reducing the LTS Purchase Price; provided, however, that VGLNG and BH acknowledge that (i) no particular result is assured or guaranteed from such price optimization efforts, (ii) price optimization efforts are not included in any Change Order (as such term is defined in the LTS Purchase Order or the PIS Purchase Order, as applicable) requested by Buyer, and (iii) the applicable Seller shall not be permitted to change the means and methods of its performance or its basis of design for the Liquefaction Train System under any Purchase Order in a manner that would deny or reduce the value to the relevant Purchaser of the benefits of the optimization of the performance of each Liquefaction Train System achieved by VGLNG and/or the relevant Purchaser. Prior to implementation, Purchaser shall consult with the applicable Seller in respect of any modifications that adversely and materially impact the inlet, exit or throughput conditions of the Liquefaction Train System. Notwithstanding the foregoing, if and to the extent that BH makes adjustments to its means and methods or design specifications under the First LTS Purchase Order that relate to BH achieving the performance guarantees set forth in the First LTS Purchase Order, such adjustments may be incorporated into each subsequent LTS Purchase Order.

 

20


3.8 Regulatory Assistance. BH shall provide all reasonably requested support and assistance to VGLNG and its subsidiaries and affiliates related to such filings or deliverables that are necessary or appropriate to submit to FERC and other regulatory authorities for the Projects, in each case, as related to BH’s scope of work, including amending any existing regulatory filings for the Projects, in accordance with the schedule set by VGLNG for submission of such filings or deliverables, [***]. VGLNG and BH acknowledge that the responsibility for FERC filings or any other regulatory or licensing filings for the Projects and successfully obtaining all necessary FERC or other regulatory or licensing approvals for the Projects are solely the responsibility and risk of VGLNG (or the applicable Purchaser).

3.9 Assistance with Tariff Exclusions and Exemptions. BH (and to the extent relevant, its affiliates and subsidiaries) shall provide reasonably requested support and assistance to VGLNG and its subsidiaries and affiliates related to such filings (including any joint filings by VGLNG or its subsidiaries and BH or its affiliates) or deliverables that are necessary or appropriate to request an exclusion or exemption from the remedies instituted in Presidential Proclamations Adjusting Imports of Steel Into the United States and Adjusting Imports of Aluminum Into the United States under Section 232 of the Trade Expansion Act of 1962, or similar tariff measures; although BH does not guarantee that it will achieve any particular results related to BH’s support so provided.

3.10 Seller Parent Guarantees. The Parties acknowledge and agree that BH’s obligations under each Purchase Order executed by a Seller and a Purchaser shall by guaranteed pursuant to a parent company guarantee in the form attached as an appendix to such Purchase Order issued by Baker Hughes Holdings LLC, a Delaware limited liability company, and delivered by the Seller to the relevant Purchaser.

3.11 Pre-Treatment System. For the avoidance of doubt, a Project shall not be required to utilize a pre-treatment system manufactured by BH, any other applicable Seller or its designee, and VGLNG shall, directly or through a subsidiary, affiliate or other entity be permitted to utilize a pre-treatment system for a Project manufactured by an entity other than BH, any applicable Seller or its designee. The Purchaser’s procurement and utilization of a pre-treatment system that is manufactured by an entity other than BH, any applicable Seller or its designee shall (a) [***]; provided, however, and contingent on the requirement that the “Basis of Design” for the pre-treatment system that is manufactured by an entity other than BH, any applicable Seller or its designee shall: (i) be substantially and materially the same as the meaning given to it in Exhibit C to this Agreement; and (ii) include no changes to the pre-treatment Basis of Design (as is defined in Exhibit C) (including pre-treatment system-caused changes to flows or qualities of the gas passing through that impact downstream equipment) that would require subsequent changes or revision to the Basis of Design for the LTS Purchase Order or the PIS Purchase Order (as the Basis for Design for each of those Purchase Orders is defined in Appendix C of Exhibit A to this Agreement and Exhibit B to this Agreement, respectively). If and to the extent that the pre-treatment system that is manufactured by an entity other than BH, another applicable Seller or its designee does not meet the requirements of clauses (i) or (ii) of the immediately preceding sentence, the applicable Seller shall be entitled to request a Change Order or other variation under the relevant LTS Purchase Order or PIS Purchase Order (including a Change Order for adjustment to the Performance Guarantee or any Minimum Performance Guarantee (as such terms are defined in the LTS Purchase Order or the PIS Purchase Order, as applicable)). Furthermore, if a Purchaser procures and utilizes a pre-treatment system that is manufactured by an entity other than BH, any applicable Seller or its designee, VGLNG acknowledges that the applicable Seller is not responsible for reviewing, endorsing, evaluating, optimizing or approving the pre-treatment system Basis of Design solution, feasibility or resulting guarantees or performance related to the pre-treatment system.

 

21


4. DISPUTES

4.1 Disputes. If a dispute arises between the Parties arising out of or relating to this Agreement, a Party shall be permitted to provide notice of the dispute to the other Party. Within ten (10) days after the receipt of such notice, or such longer time as mutually agreed to by the Parties, the Parties involved in the dispute shall meet, and the meeting shall be attended by representatives of such Parties with decision-making authority regarding the dispute, to attempt in good faith to negotiate a resolution of the dispute. If, after such meeting, the Parties have not succeeded in negotiating a resolution of the dispute, then a Party may, by delivery of written notice to the other Party, cause the dispute to be referred to a meeting of appropriate senior management of the Parties. Such meeting shall be held within thirty (30) days following the delivery of the written notice. If within thirty (30) days following the delivery of the written notice, such meeting has not been held or if within thirty (30) days following such meeting, the Parties have not succeeded in negotiating a resolution of the dispute, then either Party may refer the matter to litigation. Completion of the management settlement conference procedure set out in this Section 4.1 shall be a condition precedent to initiating litigation. The prevailing Party in any action or proceeding shall be entitled to recover from the other Party all of its reasonable costs and expenses incurred in connection with such action or proceeding, including reasonable attorneys’ fees and costs at the trial court and all appellate levels.

4.2 Jurisdiction. Each Party irrevocably consents that any legal action or proceeding against it arising out of or relating to this Agreement may be brought in any federal or state court in New York, New York, and each Party irrevocably submits to and accepts, generally and unconditionally, the jurisdiction of those courts and irrevocably agrees to be bound by any judgment rendered. Each Party irrevocably waives, to the fullest extent permitted by law, any objections which it may now or hereafter have to the venue of any such action or proceeding in New York, New York, including any claim that any action has been brought in an inconvenient forum. The Parties agree that a final judgment in any such action or proceeding shall be conclusive, and may be enforced in any other jurisdiction within or outside the United States of America.

4.3 Waiver of Right to Jury Trial or Otherwise. THE PARTIES HEREBY EXPRESSLY WAIVE ALL RIGHTS TO TRIAL BY JURY OR OTHERWISE ON ANY CLAIM, CAUSE OF ACTION, SUIT OR PROCEEDING DIRECTLY OR INDIRECTLY INVOLVING OR RELATED TO THE TERMS, COVENANTS OR CONDITIONS OF THIS AGREEMENT OR ANY MATTER WHATSOEVER ARISING OUT OF OR IN ANY WAY CONNECTED WITH OR RELATED TO THIS AGREEMENT. THIS SECTION 4.3 SHALL SURVIVE THE TERMINATION OR EXPIRATION OF THIS AGREEMENT.

4.4 Limitation on Liability. [***], TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, RULES, CODES AND REGULATIONS, NO PARTY, NOR ANY OF THEIR RESPECTIVE MEMBERS, AGENTS, OFFICERS, DIRECTORS, PARTNERS, EMPLOYEES, CONTRACTORS OR SUBCONTRACTORS SHALL BE LIABLE TO ANOTHER PARTY OR SHALL MAKE ANY CLAIM FOR ANY INCIDENTAL, INDIRECT, PUNITIVE OR CONSEQUENTIAL DAMAGES ARISING OUT OF OR CONNECTED IN ANY WAY TO THIS AGREEMENT, INCLUDING LOSS OF USE, LOSS OF PROFIT, LOSS OF BUSINESS, LOSS OF INCOME, LOSS OF REPUTATION OR ANY OTHER CONSEQUENTIAL DAMAGES THAT A PARTY MAY HAVE INCURRED FROM ANY CAUSE OF ACTION INCLUDING NEGLIGENCE, STRICT LIABILITY, BREACH OF CONTRACT AND BREACH OF STRICT OR IMPLIED WARRANTY. 

 

22


4.5 Enforcement of Agreement; Specific Performance. The Parties hereby agree that irreparable harm would occur in the event that any provision of this Agreement were not performed in accordance with its specific terms or were otherwise breached, and that money damages or other legal remedies would not be an adequate remedy for any such harm. Accordingly, the Parties acknowledge and hereby agree that, in the event of any breach or threatened breach by a Party or a Purchaser of any of its respective covenants, obligations or agreements set forth in this Agreement, the other Party shall be entitled to an injunction or injunctions to prevent or restrain breaches or threatened breaches of this Agreement by such Party, and entitled to seek to specifically enforce the terms and provisions of this Agreement to prevent and/or remedy breaches or threatened breaches of, or to enforce compliance with, the covenants, obligations and agreements of such Party under this Agreement, in addition to any other remedy to which the other Party are entitled to at law or in equity. 

5. MISCELLANEOUS

5.1 Representations and Warranties. Each Party represents and warrants to the other Party as of the Effective Date that:

(a) it is an organization duly organized and in good standing under the laws of the State of Delaware and it has the power, authority and legal right to enter into and perform its obligations under this Agreement;

(b) the execution, delivery and performance by it of this Agreement have been duly authorized by all required corporate action and do not and will not: (i) violate any applicable law or any provisions of its organizational documents or (ii) constitute or give rise to a default under any agreement or instrument to which it is a party or by which its assets may be bound; and

(c) this Agreement has been duly executed and delivered by it and constitutes its legal, valid and binding obligation, enforceable against it in accordance with its terms, except as enforceability may be limited or affected by applicable bankruptcy, insolvency, reorganization, moratorium or similar laws affecting rights of creditors generally (regardless of whether considered in a proceeding in equity or at law).

5.2 Notices. Any notice or communication from one Party to the other Party shall be in writing and shall be effective when personally delivered to the Party for whom intended, upon confirmation of receipt when sent by overnight courier (signature requested) or e-mail or five calendar (5) days following deposit of the same into the mail addressed to such Party at the address specified for the receipt of notices pursuant to this Section 5.2. The addresses initially specified by the Parties for the receipt of notices hereunder are as follows: [***]

 

23


No change of address for a Party shall be effective until written notice of the change of address is provided to the other Party in accordance with this Section 5.2.

5.3 Confidentiality. The subject matter and terms and conditions of this Agreement are considered “Confidential Information” under that certain Mutual Non-Disclosure Agreement, dated as of October 21, 2015, between BH and VGLNG, as amended by Amendment No. 1 to Mutual Non-Disclosure Agreement, dated as of February 22, 2016 and Amendment No. 2 to Mutual Non-Disclosure Agreement, dated as of August 31, 2018, among BH, VGLNG and VG Calcasieu Pass (as may be further amended from time to time, the “NDA”). All written, oral, visual or electronic information that has not been publicly disclosed and that a Party acquires from another Party shall be subject to the terms and conditions of the NDA.

5.4 Entire Agreement; Amendment. This Agreement constitutes the entire, final and exclusive agreement among the Parties with regard to the subject matter hereof and supersedes all other agreements, oral or written, among the Parties in relation to the subject matter hereof, including the First Amended and Restated Letter of Agreement, the Second Amended and Restated Letter of Agreement and the Third Amended and Restated Letter of Agreement. No cancellation, modification, amendment, deletion, addition, waiver or other change in this Agreement shall be effective unless specifically set forth in writing and signed by each of the Parties.

5.5 Binding Effect. This Agreement shall be binding upon and inure to the benefit of each of the Parties and their respective successors and permitted assigns.

5.6 Assignment. Neither Party shall transfer or assign this Agreement or any of its rights under or interest in this Agreement, without the prior written consent of the other Party, which consent shall not be unreasonably withheld, conditioned or delayed; provided, however, that VGLNG shall be permitted to transfer or assign this Agreement to any affiliate that directly or indirectly controls the entities that own the Projects without the consent of BH. Any assignment, transfer or other disposal in violation of this Section 5.6 shall be null and void ab initio and shall not be binding on the Parties.

5.7 Waiver. The waiver by a Party of a breach of any provision of this Agreement by the other Party shall not be construed as a waiver of any succeeding breach of the same or any other provision, nor shall any delay or omission on the part of a Party to exercise or avail itself of any right, power or privilege that it has, or may have, hereunder operate as a waiver of any right, power or privilege by such Party. Any consent or permission granted under this Agreement shall be effective only in the specific instance and for the specific purpose given.

 

24


5.8 Severability. Should a determination be made by a court of competent jurisdiction that any provision of this Agreement is illegal, invalid or otherwise unenforceable, the same shall not affect the other terms or provisions of this Agreement, but such provisions shall be deemed modified to the extent necessary in the court’s opinion to render such term or provision enforceable, and the rights and obligations of the Parties shall be construed and enforced accordingly, preserving to the fullest extent possible the intent and agreements of the Parties set forth herein.

5.9 Governing Law. The validity, construction and performance of this Agreement shall be governed by and construed in accordance with the laws of the State of New York, without regard to the conflict of law provisions thereof that would require the application of the laws of any other jurisdiction.

5.10 Time is of the Essence. Time is of the essence in the performance of this Agreement.

5.11 Expenses; Further Assurances. Each Party shall pay its own costs and expenses in relation to the negotiation, preparation, execution and delivery of this Agreement. Each Party shall, from time to time on being requested to do so by, and at the cost and expense of, another Party, do all such acts and/or execute and deliver all such instruments and assurances as are reasonably necessary for carrying out or giving full effect to the terms of this Agreement.

5.12 Limited Recourse. In the event of non-performance by VGLNG of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (a) any assets or properties of any of the shareholders, members or partners of VGLNG, (b) any affiliate of VGLNG or (c) any officers, directors or employees thereof, and no judgment relating to the obligations of VGLNG under this Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by BH against any shareholder, member, partner or affiliate of VGLNG or any other officer, employee or director past, present or future of VGLNG or any of its shareholders, members, partners or affiliates. In the event of non-performance by BH of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (i) any assets or properties of any of the shareholders, members or partners of BH, (ii) any affiliate of BH or (iii) any officers, directors or employees thereof, and no judgment relating to the obligations of BH under this Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by VGLNG against any shareholder, member, partner or affiliate of BH or any other officer, employee or director past, present or future of the BH or any of its shareholders, members, partners or affiliates.

5.13 Headings; Interpretation. The headings in this Agreement are for convenience only, and shall not affect the interpretation hereof. The word “includes” and variants thereof shall be deemed to mean “includes but is not limited to”. The word “Dollars” means United States dollars. The Parties acknowledge that each Party and its attorney have reviewed this Agreement and that any rule of construction to the effect that any ambiguities are to be resolved against the drafting Party, or any similar rule operating against the drafter of an agreement, shall not be applicable to the construction or interpretation of this Agreement. In no event shall this Agreement be interpreted or construed to amend, modify, supplement or waive any provision of the First LTS Purchase Order, the First PIS Purchase Order, the Second LTS Purchase Order, the Second PIS Purchase Order, the Third LTS Purchase Order or the Third PIS Purchase Order in any respect.

5.14 Counterparts. This Agreement may be executed in one or more counterparts, each of which shall be deemed an original, but all of which taken together shall constitute one and the same instrument. Signatures may be delivered electronically or by facsimile, and such copies shall be treated as originals for all purposes.

[SIGNATURES APPEAR ON THE FOLLOWING PAGE]

 

25


IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed by their duly authorized representatives as of the date first above written.

 

VENTURE GLOBAL LNG, INC.
By:  

/s/ Keith Larson

Name:   Keith Larson
Title:   General Counsel
BAKER HUGHES ENERGY SERVICES LLC
By:  

/s/ Marco Caccavale

Name:   Marco Caccavale
Title:   President


Exhibit A

Form of LTS Purchase Order

[Omitted]

 

A-1


Exhibit B

Form of PIS Purchase Order

[Omitted]

 

B-1


Exhibit C

Basis of Design for Pre-Treatment System

[Omitted]

 

C-1


Exhibit D

Adjustment Factors

1. Liquefaction Train System Escalation Formula

Escalation Formula

Component (1) of the LTS Purchase Price for each LTS Purchase Order will be adjusted by the following adjustment index formula, provided that such adjustment shall (a) not be subject to any compounding and (b) be limited to a maximum reduction of [***], and maximum increase of [***], per annum:

[***]

where:

[***]

and:

[***]

 

D-1


2. Power Island System Escalation Formula

OECD + BLS formula mechanism

Escalation Formula

The PIS Purchase Price for each PIS Purchase Order will be adjusted by the following adjustment index formula, provided that the adjustment of each PIS Purchase Price (a) will not be subject to any compounding and (b) be limited to a maximum reduction of [***], and maximum increase of [***], per annum:

[***]

where:

[***]

and:

[***]

Index References

OECD Indices overview:

OECD Purchasers Price Index

https://data.oecd.org/price/producer-price-indices-ppi.htm

Euro area (19 countries)

BLS Index overview:

BLS: Bureau of Labor Statistics

http://data.bls.gov/timeseries/PCU333132333132

Bureau of Labor Statistic index for “oil & gas field machinery & equipment mfg”

 

D-2


Exhibit E

Foreign Exchange Adjustment

1. The LTS Purchase Price shall be adjusted for foreign exchange as follows:

 

  (a)

For the Fourth LTS Purchase Order, the Fifth LTS Purchase Order and the Sixth LTS Purchase Order:

 

  (i)

An amount in US Dollars equal to [***] of Component (1) of the LTS Purchase Price shall be converted from US Dollars into Euro at the exchange rate for US Dollars to Euro as of July 13, 2016, which is stipulated to be [***] US Dollar to [***] Euro; and

 

  (ii)

The Euro amount determined pursuant to clause (a)(i) shall be re-converted to US Dollars on the day immediately preceding the date of execution of the relevant LTS Purchase Order, using the Euro reference exchange rate for the US Dollar published by the European Central Bank at link https://www.ecb.europa.eu/stats/ policy_and_exchange_rates/euro_reference_exchange_rates/html/index.en.html and determined by the parties to the Purchase Order between 11:00 a.m. and 5:00 p.m. Eastern Prevailing Time on the day immediately preceding the date of execution of the relevant LTS Purchase Order.

 

  (iii)

An amount in US Dollars equal to [***] of Component (1) of the LTS Purchase Price shall be subtracted from the re-converted US Dollar amount determined pursuant to clause (a)(ii) and;

 

  (iv)

If the amount determined pursuant to clause (a)(iii) is positive, it shall be added to Component (1) of the LTS Purchase Price. If the amount determined pursuant to clause (a)(iii) is negative, it shall be subtracted from Component (1) of the LTS Purchase Price.

 

  (b)

For the Seventh LTS Purchase Order, the Eighth LTS Purchase Order, the Ninth LTS Purchase Order, the Tenth LTS Purchase Order, the Eleventh LTS Purchase Order, the Twelfth LTS Purchase Order and the Final LTS Purchase Order:

 

  (i)

An amount in US Dollars equal to [***] of Component (1) of the LTS Purchase Price shall be converted from US Dollars into Euro at the exchange rate for US Dollars to Euro as of July 13, 2016, which is stipulated to be [***] US Dollar to [***] Euro;

 

  (ii)

The Euro amount determined pursuant to clause (b)(i) shall be re-converted to US Dollars on the day immediately preceding the date of execution of the relevant LTS Purchase Order, using the Euro reference exchange rate for the US Dollar published by the European Central Bank at link https://www.ecb.europa.eu/stats/ policy_and_exchange_rates/euro_reference_exchange_rates/html/index.en.html and determined by the parties to the Purchase Order between 11:00 a.m. and 5:00 p.m. Eastern Prevailing Time on the day immediately preceding the date of execution of the relevant LTS Purchase Order;

 

  (iii)

An amount in US Dollars equal to [***] of Component (1) of the LTS Purchase Price shall be subtracted from the re-converted US Dollar amount determined pursuant to clause (b)(ii), and the difference in such amount (positive or negative) shall be divided by two (2); and;


  (iv)

If the amount determined pursuant to clause (b)(iii) is positive, it shall be added to Component (1) of the LTS Purchase Price. If the amount determined pursuant to clause (b)(iii) is negative, no amount shall be deducted from Component (1) of the LTS Purchase Price.

2. The PIS Purchase Price shall be adjusted for foreign exchange as follows:

 

  (a)

For each of the Fourth PIS Purchase Order, the Fifth PIS Purchase Order, the Sixth PIS Purchase Order, the Seventh PIS Purchase Order, the Eighth PIS Purchase Order, the Ninth PIS Purchase Order, the Tenth PIS Purchase Order, the Eleventh PIS Purchase Order, the Twelfth PIS Purchase Order and the Final PIS Purchase Order:

 

  (i)

An amount in US Dollars equal to [***] of the PIS Purchase Price, which is specifically associated with the five (5) generators for the gas turbines, two (2) generators for the steam turbines, the gas insulated switchgear and the generator circuit-breakers of the Power Island System, shall be converted from US Dollars into Euro at the exchange rate for US Dollars to Euro as of July 13, 2016, which is stipulated to be [***] US Dollars to [***] Euro.

 

  (ii)

An amount in US Dollars equal to [***] of the PIS Purchase Price, which is specifically associated with the two (2) steam turbines of the Power Island System, shall be converted from US Dollars into Polish Zloty (PLN) at the exchange rate for US Dollars to PLN as of July 13, 2016, which is stipulated to be [***] US Dollars to [***] PLN.

 

  (iii)

The Euro amount determined pursuant to clause (a)(i) shall be re-converted to US Dollars on the day immediately preceding the date of execution of the relevant PIS Purchase Order, using the Euro reference exchange rate for the US Dollar published by the European Central Bank at link https://www.ecb.europa.eu/stats/ policy_and_exchange_rates/euro_reference_exchange_rates/html/index.en.html and determined by the parties to the PIS Purchase Order between 11:00 a.m. and 5:00 p.m. Eastern Prevailing Time on the day immediately preceding the date of execution of the relevant PIS Purchase Order.

 

  (iv)

The PLN amount determined pursuant to clause (a)(ii) shall be re-converted to US Dollars on the day immediately preceding the date of execution of the relevant PIS Purchase Order, using the middle exchange rate (table A) for the US Dollar published by Narodowy Bank Polski at link https://www.nbp.pl/homen.aspx?f=/kursy/ratesa.html and determined by the parties to the PIS Purchase Order between 11:00 a.m. and 5:00 p.m. Eastern Prevailing Time on the day immediately preceding the date of execution of the relevant PIS Purchase Order.

 

  (v)

An amount in US Dollars equal to [***] of the PIS Purchase Price shall be subtracted from the re-converted US Dollar amount determined pursuant to clause (a)(iii).

 

  (vi)

If the amount determined pursuant to clause (a)(v) is positive, it shall be added to the PIS Purchase Price. If the amount determined pursuant to clause (a)(v) is negative, it shall be deducted from the PIS Purchase Price.

 

  (vii)

An amount in US Dollars equal to [***] of the PIS Purchase Price shall be subtracted from the re-converted US Dollar amount determined pursuant to clause (a)(iv).


  (viii)

If the amount determined pursuant to clause (a)(vii) is positive, it shall be added to the PIS Purchase Price. If the amount determined pursuant to clause (a)(vii) is negative, it shall be deducted from the PIS Purchase Price.

 

  (b)

If at any time the manufacturing of any of gas or steam turbine generators, the gas insulated switchgear, the generator circuit-breakers or any steam turbines supplied under any PIS Purchase Order described in clause (a) is performed under a subcontract made in US Dollars or if any such generator or steam turbine is manufactured in the United States of America, then the corresponding foreign currency adjustment(s) set forth in clause(a)(i) and/or clause(a)(ii) above shall not apply to such PIS Purchase Order.

3. For the avoidance of doubt, any adjustment to the percentages specified in this Exhibit E shall be subject to Section 5.4 of the Agreement.


Exhibit F

Areas A&B

[Omitted]

Exhibit 10.33

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

AMENDED AND RESTATED PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

THIS AMENDED AND RESTATED PURCHASE ORDER CONTRACT FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM (hereinafter this “Agreement”) is entered into as of January 19, 2022 (the “Effective Date”) by and between BAKER HUGHES ENERGY SERVICES LLC, a limited liability company organized and existing under the laws of the State of Delaware, with an address and place of business at 17021 Aldine Westfield Road, Houston, Texas 77073 (hereinafter the “Seller”), and VENTURE GLOBAL PLAQUEMINES LNG, LLC, a limited liability company organized and existing under the laws of the State of Delaware, with an address at 1001 19th Street North, Suite 1500, Arlington, VA 22209 (hereinafter the “Buyer”).

The Buyer and the Seller are referred to herein individually as a “Party” and collectively as the “Parties”.

RECITALS

WHEREAS, Venture Global LNG, Inc. (“VGLNG”), through its subsidiaries, is developing certain LNG export facilities within the United States of America, including the Facility, as defined in Appendix A (General Terms & Conditions);

WHEREAS, Seller designs, engineers, fabricates and manufactures certain natural gas liquefaction equipment in Seller’s affiliated manufacturing facilities;

WHEREAS, Seller sells Liquefaction Train Systems, as defined in Appendix A (General Terms & Conditions);

WHEREAS, Seller and Buyer are parties to that certain Purchase Order Contract for the Sale of Liquefaction Train System, dated as of February 26, 2021, in respect to the Liquefaction Train System (the “Original Purchase Order”), as supplemented by Change Order No. 1 Under the Purchase Order Contract For The Sale of Liquefaction Train System, dated as of September 30, 2021, and the Limited Notice to Proceed Under The Purchase Order Contract For The Sale of Liquefaction Train System, dated as of September 30, 2021, issued pursuant to Clause 6.6 of the Original Purchase Order (the “LNTP No. 1”);

WHEREAS, Seller is providing, subject to the terms and conditions of this Agreement, an Unconditional Performance Obligation (as defined herein) with production and efficiency standards for the Liquefaction Train System forming part of the process system of the Facility; and

WHEREAS, Buyer and Seller desire to amend and restate the terms and conditions of the Original Purchase Order as set forth in this Agreement.


NOW, THEREFORE, in consideration of these Recitals, the mutual covenants, promises and agreements contained herein, and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound, the Parties agree as follows:

 

1.

SCOPE OF SUPPLY

Seller agrees to manufacture, sell and deliver the Liquefaction Train System as set forth in Appendix C (Scope of Supply & Project Schedule) to this Agreement.

 

2.

PRICE AND PAYMENT

In consideration of the supply of a Liquefaction Train System as described in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule), the Buyer will pay to the Seller the contract price in the increments and on the payment schedule as specified in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule). Termination and cancellation charges shall be as specified in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule).

 

3.

PERIOD OF PERFORMANCE

Seller shall complete the performance of all of its obligations set forth in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule) in accordance with the activity completion and delivery schedule described in Appendix C (Scope of Supply & Project Schedule) and the terms of this Agreement. The Liquefaction Train System shall be delivered subject to the Incoterms 2010 as described in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule). Buyer shall complete performance of all of its obligations set forth in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule) in accordance with the terms of this Agreement.

 

4.

TERMS AND CONDITIONS

The following terms and conditions are applicable to this Agreement. The Agreement between the Parties shall be comprised of and consists of the following documents (the “Order Documents”), each of which shall be read and construed as an integral part of the Agreement, listed in order of precedence in case of dispute:

 

1.   

This document;

2.    Appendix A:   General Terms & Conditions;
3.    Appendix B:   Pricing; Payment Terms & Cancellation Schedule;
4.    Appendix C:   Scope of Supply & Project Schedule;
5.    Appendix D:   [Intentionally Omitted];
6.    Appendix E:   Quality Assurance and Quality Control;
7.    Appendix F:   Performance Tests;
8.    Appendix G:   Approved Subcontractors;

 

2


9.

   Appendix H:  

[Intentionally Omitted]

10.

   Appendix I:  

Form of Change Order;

11.

   Appendix J:  

Form of Lien Waivers and Releases;

     J-1    Seller Form of Partial Lien Waiver and Release;
     J-2    Seller Form of Final Lien Waiver and Release;
     J-3    Subcontractor Form of Partial Lien Waiver and Release;
     J-4    Subcontractor Form of Final Lien Waiver and Release;
12.    Appendix K:   Transportation Costs; and
13.    Appendix L:   Liquidated Damage Amounts.

 

5.

LIMITED RECOURSE

Excepting to the extent as otherwise provided in any parent guarantee provided to Seller under this Agreement, in the event of non-performance by Buyer of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (a) any assets or properties of any of the shareholders, members or partners of the Buyer, (b) any Affiliate of Buyer or (c) any officers, directors or employees thereof, and no judgment relating to the obligations of Buyer under this Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of Buyer or any other officer, employee or director past, present or future of the Buyer or any of its shareholders, members, partners or Affiliates. Excepting to the extent as otherwise provided in any parent guarantee provided to Buyer under this Agreement, in the event of non-performance by Seller of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (a) any assets or properties of any of the shareholders, members or partners of the Seller, (b) any Affiliate of Seller or (c) any officers, directors or employees thereof, and no judgment relating to the obligations of Seller under this Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of the Seller or any other officer, employee or director past, present or future of the Seller or any of its shareholders, members, partners or Affiliates.

 

6.

ENTIRE AGREEMENT

The Order Documents making up the Agreement, excluding for the avoidance of doubt that certain Second Amended and Restated Letter of Agreement, dated as of February 26, 2021, by and between Seller and VGLNG, as amended by Amendment No. 1 to Second Amended and Restated Letter of Agreement dated as of the date hereof (as further amended, amended and restated, supplemented, or otherwise modified from time to time, the “Letter of Agreement”), constitute and represent the entire agreement between the Parties and supersede in their entirety any and all prior agreements or understandings concerning the subject matter hereof, and no modification, amendment, revision, waiver, or other change shall be binding on either Party unless consented to

 

3


in writing by the Parties or their authorized representatives. Any oral or written representation, warranty, course of dealing or trade usage not contained or referenced herein shall not be binding on either Party. Each Party agrees that it has not relied on, or been induced by, any representations of the other Party not contained in this Agreement.

 

7.

GOVERNING LAW; DISPUTE RESOLUTION

This Agreement shall be subject to the dispute resolution and governing law provisions as further described in Clause 20 and Clause 21 of Appendix A (General Terms & Conditions).

 

8.

INTERPRETATION

Capitalized terms used in this Agreement that are not otherwise defined shall have the meaning given in Appendix A (General Terms & Conditions) and the rules of interpretation set forth in Clause 1.2 of Appendix A (General Terms & Conditions) shall apply to this Agreement.

[SIGNATURES APPEAR ON THE FOLLOWING PAGE]

 

4


IN WITNESS WHEREOF the Parties have caused this Agreement to be executed by their authorized representatives on the Effective Date.

 

SELLER:     BUYER:
BAKER HUGHES ENERGY SERVICES LLC     VENTURE GLOBAL PLAQUEMINES LNG, LLC
By:  

/s/ Marco Caccavale

    By:  

/s/ Keith Larson

Name:   Marco Caccavale     Name:   Keith Larson
Title:   Vice President, TPS Sales     Title:   General Counsel and Secretary


APPENDIX A

GENERAL TERMS & CONDITIONS

 

1.

DEFINITIONS AND INTERPRETATION

 

1.1

Definitions.

Unless otherwise defined elsewhere in the Agreement, the following terms shall have the following meanings:

Affiliate” with respect to a Party means an entity (including without limitation any individual, corporation, partnership, limited liability company, association or trust) controlling, controlled by or under common control with that Party. As used herein, “control” means the possession, directly or indirectly, of the power to direct or cause the direction of the management of policies of such Party, whether through the ownership of voting securities or other interest, by contract or otherwise. For the avoidance of doubt, for the purposes of this Agreement Venture Global Calcasieu Pass, LLC shall not be deemed to be an Affiliate of Buyer.

Aggregate Delivery Delay Liquidated Damages Cap” means an amount equal to [***] of the Contract Price.

Aggregate Performance Delay Liquidated Damages Cap” means an amount equal to [***] of the Contract Price.

Anti-Corruption Laws” has the meaning given to it in Clause 16.5(b).

Approved Subcontractors” means the Subcontractors listed under “Selected Subcontractors” in Appendix G (Approved Subcontractors) of the Agreement and that are otherwise proposed by Seller and approved by Buyer in accordance with Clause 4.2.

Background Intellectual Property” means all Intellectual Property, relevant to this Agreement, that a Party created or acquired before February 26, 2021 or that a Party creates or acquires independently of the Agreement and not in the performance of its obligations hereunder.

Bankruptcy Event” means, with respect to a Person, that such Person: (a) files a petition or otherwise commences, or authorizes the commencement of, a proceeding or cause under any bankruptcy, insolvency, receivership or similar law for the protection of creditors; (b) has such a petition filed or proceeding commenced against it, which remains undismissed for ninety (90) Days; (c) files an answer or pleading admitting or failing to contest the material allegations of any such petition; (d) takes any action for its winding up, liquidation or dissolution; (e) is otherwise adjudged bankrupt or insolvent under any bankruptcy, insolvency, receivership or similar law for the protection of creditors; or (f) consents to any of the actions described in clauses (a) through (e) of this definition being taken against it.

 

A-1


BAR Policy” has the meaning given to it in Clause 23.4.

Basis of Design” has the meaning given to it in Appendix C (Scope of Supply & Project Schedule).

Benefitted Party” has the meaning given to it in Clause 8.2.

BH-Transient Liquefaction Train Simulation Model” has the meaning given to it in Clause 18.9.

Buyer” has the meaning given to it in the preamble of the Agreement.

Buyer Developed Intellectual Property” has the meaning given to it in Clause 18.4.

Buyer Excluded Parties” means Buyer, Owner and each of their Affiliates, Venture Global Calcasieu Pass, LLC and all other entities directly or indirectly owned by Venture Global LNG, Inc., and each of their subsidiaries, owners, shareholders and all of their respective directors, officers, assigns and employees, and the EPC Contractor (and EPC Contractor’s respective affiliates, subsidiaries, owners, shareholders and its respective directors, officers, assigns and employees).

Buyer Inspection Parties” means Buyer, Owner, Owner’s customers, Lenders, Lender’s Engineer and their respective representatives and agents.

Buyer Parent Company Guarantee” means the guarantee dated February 26, 2021 issued by Buyer’s parent company to Seller in accordance with Clause 7.8.

Buyer Parties” means Buyer, Owner, the Lenders and each of their Affiliates and all of their respective directors, officers, agents, advisors, engineers, contractors, consultants, representatives, assigns, employees and any other Person acting on behalf of any of them or in representation, interest, benefit thereto.

Buyer Taxes” means any and all existing or future taxes, Duties, fees, or other charges of any nature (including, but not limited to, ad valorem, consumption, excise, franchise, gross receipts, import, export, license, property, sales and use, stamp, storage, transfer, turnover, or value-added taxes, or other similar taxes, and any and all items of deficiency, penalty, addition to tax, interest, or assessment related thereto), imposed by any Governmental Authority of the United States of America (or any political subdivision thereof) in connection with the execution of the Agreement or the purchase of the Liquefaction Train System, but excluding Seller Taxes.

Buyer’s Representatives” has the meaning given to it in Clause 22.1.

Calcasieu Purchase Order” means the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of September 25, 2018, between Seller and Venture Global Calcasieu Pass, LLC.

Change Order” has the meaning given to it in Clause 24.1.

 

A-2


Cold Box” means the Liquefaction Train cold box, as further described in Appendix C (Scope of Supply & Project Schedule).

Confidential Information” has the meaning given to it in Clause 22.1.

Contract Price” means the aggregate amount stated in Clause 7.1 for the purchase of the Liquefaction Train System, as further described in Appendix B (Pricing; Payment Terms & Cancellation Schedule) and as such amount may be modified pursuant to a Change Order signed by Seller and Buyer in accordance with the requirements of the Agreement.

Costs” means all reasonable and documented expenses, costs and third party disbursements incurred by a Party, but excluding any such expenses, costs and disbursements that are excluded pursuant to Clause 19.3.

Country” means the United States of America.

Credit Rating” means the current (a) rating issued or maintained by S&P or Moody’s with respect to such entity’s long-term senior, unsecured, unsubordinated debt obligations (not supported by third party credit enhancements) or (b) corporate credit rating or long-term issuer rating issued or maintained with respect to such entity by S&P or Moody’s.

Day” means a calendar day, i.e. any twenty-four (24) hour period beginning and ending at 12:00 midnight in the State of Louisiana, unless otherwise specified herein as starting from a specific hour.

Defect” means a failure to meet any warranty set forth in Clause 17.1.

Delay Limit Date” means the date on which Seller has accrued an aggregate amount of Delivery Delay Liquidated Damages in an amount equal to or greater than (a) the applicable Delivery Delay Liquidated Damages Cap, or (b) Aggregate Delivery Delay Liquidated Damages Cap.

 

Delivery Delay Event” means each instance in which Seller fails to deliver a Liquefaction Train (in its entirety) or Deliverable, as applicable, by its associated Delivery Date.

Delivery Delay Liquidated Damages” has the meaning given to it in Clause 6.4(a).

Delivery Delay Liquidated Damages Cap” means, in respect of each Liquefaction Train, an amount equal to (a) [***] of the Aggregate Delivery Delay Liquidated Damages Cap in respect of each of the first [***] Liquefaction Trains to be delivered, and (b) [***] of the Aggregate Delivery Delay Liquidated Damages Cap in respect of each of the subsequent [***] Liquefaction Trains to be delivered.

Deliverables” means all information, including the Technical Documentation, that was first conceived, reduced to practice or created by Seller or its employees or Subcontractors in the performance of its obligations under the Agreement, a list of which is set forth in Appendix C (Scope of Supply & Project Schedule).

 

A-3


Delivery Date” means, for each Liquefaction Train or Deliverable, as applicable, the date on which such Liquefaction Train or Deliverable, as applicable, is required to be delivered by Seller to Buyer (pursuant to the Incoterms of the Agreement) in accordance with the Agreement, as further described in the Project Schedule.

Delivery Point” has the meaning given to it in Clause 9.1.

Disclosing Party” has the meaning given to it in Clause 22.1.

Dispute” has the meaning given to it in Clause 20.1.

Dollars” means the lawful currency of the United States of America.

Duties” has the meaning given to it in Clause 7.1.

EAR” has the meaning given to it in Clause 16.2.

EDR File” has the meaning given to it in Clause 18.6.

Effective Date” has the meaning given to it in the preamble of the Agreement.

EPC Agreement” means the agreement that Owner enters into with one or more Persons for the construction of the Facility.

EPC Contractor” means any Person (other than Owner) that is a party to the EPC Agreement.

Event of Default” means an event of default of Seller described in Clause 28.1 or an event of default of Buyer described in Clause 28.2, which in each case has not been cured within the applicable cure period, if any, as provided by the terms of such Clauses.

Facility” means the initial phase of the LNG export terminal and liquefaction project to be located at the Site.

Factory Acceptance Tests” has the meaning given to it in Clause 14.5.

Finance Agreements” means the agreements entered into or to be entered into between Owner or its Affiliates and the Lenders and the other documents related thereto for the purpose of providing financing, refinancing or other financial services for the Facility.

Financial Closing” means that all of the conditions precedent set forth in the Finance Agreements shall have been satisfied or waived and the Lenders party thereto have disbursed the initial loans thereunder.

FNTP” has the meaning given to it in Clause 6.6.

 

A-4


Force Majeure Event” has the meaning given to it in Clause 33.1.

Force Majeure Report” has the meaning given to it in Clause 33.4.

Governmental Authority” means any federal, state, regional, city or local government, any intergovernmental association or political subdivision thereof, or other governmental, regulatory or administrative agency, court, commission, administration, department, board, or other governmental subdivision, legislature, rulemaking board, tribunal or other governmental authority with jurisdiction over Seller, Seller Parties (as may be applicable), Buyer, Owner, EPC Contractor, the Liquefaction Train System(s) or any part thereof or the Site, or any Person acting as a delegate or agent of any Governmental Authority.

Government Official” has the meaning given to it in Clause 16.5(c).

Guaranteed Liquefaction Train Substantial Completion Date” means, with respect to a Liquefaction Train, the last day of the Liquefaction Train Testing Period (as defined in Appendix F (Performance Tests)) for such Liquefaction Train, on which Substantial Completion of the Liquefaction Train for such Liquefaction Train is required to be achieved.

Guaranteed Liquefaction Train System Substantial Completion Date” means the last day of the Liquefaction Train System Testing Period (as defined in Appendix F (Performance Tests)), on which Substantial Completion of the Liquefaction Train System is required to be achieved.

Hazardous Materials” means any chemical, substance, material or emission, including H2S gas, that is or may be regulated, governed, listed or controlled pursuant to any international, national, federal, provincial, state or local statute, ordinance, order, directive, regulation, judicial decision or other legal requirement applicable to Site as a toxic substance, hazardous substance, hazardous material, dangerous or hazardous waste, dangerous good, pesticide, radioactive material, regulated substance or any similar classification, or any other chemical, substance, emission or material, including, without limitation, petroleum or petroleum-derived products or by-products, regulated, governed, listed or controlled or as to which liability is imposed on the basis of potential impact to safety, health or the environment pursuant to any rule or regulation promulgated by any Governmental Authority.

ICC Rules” has the meaning given to it in Clause 20.2.

Instruments of Service” has the meaning given to it in Clause 18.5.

Intellectual Property” means all intellectual property and proprietary rights thereto, including all rights of inventorship and authorship, inventions, patents, patent applications, patent disclosures, know-how, processes, methods, machines, manufactures, designs, compositions of matter, or any new or useful improvement thereof, copyrights, copyright registrations and applications for copyright registration, trademark, trade dress and service mark rights and registrations and applications for registration thereof, and all rights in trade secrets, computer software, data and databases, and mask works, all rights of attribution and integrity and other moral rights and all other intellectual property rights of any type, in each case whether registered or unregistered and including all applications for, and renewals and extensions of such rights and all similar or equivalent rights or forms of protection in any part of the world.

 

A-5


Intellectual Property Claim” means any claim, demand, suit or legal action arising out of or based on any actual or alleged unauthorized disclosure, use or misappropriation of any Intellectual Property, or, any actual or alleged infringement or other violation of any right in, to or under, any Intellectual Property of any other Person that: (a) concerns any materials, deliverables, Work Product or other services provided by Seller, any of its Affiliates, or any Subcontractor under the Agreement; (b) is based upon or arises out of the performance under the Agreement by Seller, any of its Affiliates, or any Subcontractor, including the use of any tools or other implements of construction by Seller, any of its Affiliates, or any Subcontractor; or (c) is based upon or arises out of Buyer’s exercise of its rights pursuant to and in accordance with Clause 18.

Key Personnel” means the project director appointed by Seller pursuant to Clause 3, each deputy project director and any other senior supervisory personnel as agreed between the Parties in writing.

kWh” means kilowatt hour.

Law” means all constitutions, treaties, laws, statutes, edicts, decrees, ordinances, rules, regulations, tariffs, codes, injunctions, writs, requirements, instructions, order and other legal acts of any Governmental Authority or any body under the control of a Governmental Authority.

Lender” means (i) any Person that does or proposes to lend money, finance or provide financial support or equity in any form in respect of the Facility and/or the general business and operations of Owner or each of its Affiliates (including any refinancing thereof), including any export credit agency, funding agency, bondholder, insurance agency, underwriter, investor, commercial lender or similar institution, together with any agent or trustee for such Person and (ii) any provider of any hedging arrangement entered into in connection with the arrangements described in clause (i) above, including an interest rate swap transaction or a forward interest rate swap transaction, in each case together with any agent or trustee for such provider.

Lender’s Engineer” is any Person appointed by the Lenders to represent them on technical matters related to the Facility.

Letter of Agreement” has the meaning set forth in Section 6 of the Agreement.

Lien” means any mortgage, deed of trust, pledge, lien, security interest, option agreement, conditional sale agreement, title retention agreement, claim, equity, attachment, covenant, condition or restriction, charge or encumbrance or any agreement of any kind, in or with respect to any real or personal property.

Liquefaction Train” means the mixed refrigerant compression package, including the Cold Box, surge vessel and other equipment purchased by Buyer from Seller producing approximately six hundred twenty-six thousandth (0.626) MTPA of LNG at design outlet pressure and ambient design conditions of [***] degrees Fahrenheit and [***] relative humidity, at sea level, as further described in Appendix C (Scope of Supply & Project Schedule).

 

A-6


Liquefaction Train Performance Guarantees” means the Liquefaction Train Production Capacity Performance Guarantee and the Liquefaction Train Power Demand Performance Guarantee.

Liquefaction Train Performance Tests” means the Liquefaction Train performance tests described in Appendix F (Performance Tests).

Liquefaction Train Power Demand Minimum Performance Guarantee” means power demand for a Liquefaction Train of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train Production Capacity Performance Guarantee.

Liquefaction Train Power Demand Performance Guarantee” means power demand for a Liquefaction Train of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train Production Capacity Performance Guarantee.

Liquefaction Train Power Demand Liquidated Damages” has the meaning given to it in Clause 25.3(a).

Liquefaction Train Production Capacity Performance Guarantee” means LNG production capacity of [***] MTPA.

Liquefaction Train Production Capacity Liquidated Damages” has the meaning given to it in Clause 25.3(b).

Liquefaction Train System” means the mixed refrigerant compression package, including the Cold Box, surge vessel and other equipment purchased by Buyer from Seller in a configuration of [***] Liquefaction Trains capable of producing an aggregate of approximately [***] MTPA of LNG at design conditions, as further described in Appendix C (Scope of Supply & Project Schedule).

Liquefaction Train System Performance Guarantees” means the Liquefaction Train System Production Capacity Performance Guarantee, the Liquefaction Train System Power Demand Performance Guarantee, the Refrigerant Losses Performance Guarantee and the LNG Quality Performance Guarantee.

Liquefaction Train System Performance Delay Liquidated Damages Cap” means an amount equal to [***] of the Aggregate Performance Delay Liquidated Damages Cap.

Liquefaction Train System Performance Tests” means the Liquefaction Train System performance tests described in Appendix F (Performance Tests).

Liquefaction Train System Power Demand Minimum Performance Guarantee” means power demand for the Liquefaction Train System of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train System Production Capacity Performance Guarantee.

 

A-7


Liquefaction Train System Power Demand Performance Guarantee” means power demand for the Liquefaction Train System of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train System Production Capacity Performance Guarantee.

Liquefaction Train System Power Demand Liquidated Damages” has the meaning given to it in Clause 25.3(a).

Liquefaction Train System Production Capacity Performance Guarantee” means LNG production capacity for the Liquefaction Train System of 15.024 MTPA and [***] at [***] and [***], without considering the maintenance cycle for the Liquefaction Trains.

Liquefaction Train System Production Capacity Liquidated Damages” has the meaning given to it in Clause 25.3(b)(ii).

Liquidated Damages” means Delivery Delay Liquidated Damages, Performance Delay Liquidated Damages and the Performance Liquidated Damages, collectively.

Liquidated Damages Cap” means an amount equal to [***] of the Contract Price.

LNG” has the meaning given to it in the Basis of Design.

LNG Quality Performance Guarantee” means that the LNG composition meets the criteria in Annex C-2 of Appendix C (Scope of Supply & Project Schedule).

LNG Quality Liquidated Damages” has the meaning given to it in Clause 25.3(b)(ii).

LNTP” has the meaning given to it in Clause 6.6.

LNTP Advance” means the non-refundable payment made by Buyer to Seller of the sum of [***] representing the partial advance payment in respect of LNTP No. 1.

LNTP No. 1” has the meaning given to it in the recitals of the Agreement.

Losses” means any and all losses, liabilities, damages, costs, charges, expenses, fines, interest, awards, penalties and taxes, which are the result of or arise in connection with any actions, suits, claims, demands, causes of action, litigation, lawsuits, administrative proceedings or administrative investigations.

Major Component” has the meaning given to it in Clause 4.2.

 

A-8


Major Subcontractor” means any Subcontractor identified in Appendix G having a contract with Seller in relation to Seller’s performance of this Agreement with an aggregate value in excess of One Million Dollars ($1,000,000). 

Maximum Termination Fee” has the meaning given to it in Clause 29.2.

Milestone” means an event that is identified as a milestone in the Project Schedule.

Minimum Performance Guarantees” means the Liquefaction Train Power Demand Minimum Performance Guarantee, the Liquefaction Train System Power Demand Minimum Performance Guarantee, and the Refrigerant Losses Performance Guarantee.

Mixed Refrigerant” means a mixture of gases or liquids, including ethylene, propane, i-pentane, nitrogen and other gases as may be required to operate a Liquefaction Train.

Module” means the natural gas liquefaction module forming part of a Liquefaction Train, as further described in Appendix C (Scope of Supply & Project Schedule).

Month” means a calendar month according to the Gregorian Calendar beginning at 12:00 midnight in the State of Louisiana, on the last Day of the preceding month and ending at 12:00 midnight in the State of Louisiana, on the last Day of the current month, unless otherwise specified herein as from another Day to the Day preceding the same Day of following Month.

Moody’s” means Moody’s Investor Services, Inc. and any successor thereto.

MTPA” means million Tonnes of LNG per annum.

Notice of Dispute” has the meaning given to it in Clause 20.1.

Operation And Maintenance Manuals” means the manuals described as such in Appendix C (Scope of Supply & Project Schedule).

Original Purchase Order” has the meaning given to it in the recitals of the Agreement.

Other Party” has the meaning given to in Clause 8.2.

Outside Intellectual Property” has the meaning given to it in Clause 18.6.

Owner” means Venture Global Plaquemines LNG, LLC and any of its successors and assigns.

Party” or “Parties” has the meaning given to it in the preamble of the Agreement.

Payment Milestone” means the event or group of events to be achieved in order to entitle Seller to invoice the payment, as listed in Appendix B (Pricing; Payment Terms & Cancellation Schedule).

 

A-9


Payment Schedule” has the meaning given to it in Clause 7.1.

Performance Delay Liquidated Damages” means the Liquefaction Train Production Capacity Liquidated Damages, the Liquefaction Train System Production Capacity Liquidated Damages and the LNG Quality Liquidated Damages.

Performance Delay Liquidated Damages Cap” means: (a) in respect of each Liquefaction Train, an amount equal to (i) [***] of the Aggregate Performance Delay Liquidated Damages Cap in respect of each of the first [***] Liquefaction Trains to be performance tested and (ii) [***] of the Performance Delay Liquidated Damages Cap in respect of each of the subsequent [***] Liquefaction Trains to be performance tested; and (b) in respect of the Liquefaction Train System Production Capacity Performance Guarantee and the LNG Quality Performance Guarantee, collectively, an amount equal to [***].

Performance Guarantees” means the Liquefaction Train Performance Guarantees and the Liquefaction Train System Performance Guarantees.

Performance Liquidated Damages” means the Liquefaction Train Power Demand Liquidated Damages and the Liquefaction Train System Power Demand Liquidated Damages.

Performance Liquidated Damages Cap” means an amount equal to [***].

Performance Tests” means the Liquefaction Train Performance Tests and the Liquefaction Train System Performance Tests.

Person” means any individual, corporation, partnership, joint venture, limited liability company, association, joint stock company, trust, unincorporated organization, entity, government or other political subdivision.

PIS Purchase Order” means that certain Purchase Order Contract for the Sale of Power Island System, dated as of February 26, 2021, in relation to the sale of a power island system described therein by Seller to Buyer, as amended, amended and restated, supplemented, or otherwise modified from time to time.

Preservation Agreement” means the agreement that Buyer and Seller may negotiate and enter into pursuant to which (a) some or all of the Liquefaction Trains will be stored in a storage facility meeting Seller’s requirements for [***] or more, up to [***], and (b) Seller will for commercially reasonable market-based rates provide Buyer with preservation and maintenance services for such Liquefaction Trains while such Liquefaction Trains are in stored in the storage facility.

Project Schedule” means the activity completion and delivery schedule set forth in Appendix C (Scope of Supply & Project Schedule).

 

A-10


Qualified Financial Institution” means a U.S. commercial bank or a U.S. branch office of a foreign bank having, in either case, (a) assets of at least $10,000,000,000 and (b) a Credit Rating from one or both of S&P and Moody’s, which Credit Rating is at least “A-” from S&P (if such bank has a Credit Rating from S&P) and “A3” from Moody’s (if such bank has a Credit Rating from Moody’s).

Ready for Test” means that the Liquefaction Train or the Liquefaction Train System, as applicable, (i) has been installed and is mechanically complete, (ii) has completed Seller’s commissioning and start-up activities pursuant to the Services Agreement, (iii) is capable of being operated safely in accordance with requirements under the EPC Agreement, and (iv) is ready for the Performance Tests to be performed in accordance with the Agreement.

Rebatable Louisiana Sales and Use Tax” has the meaning given to it in Clause 8.2.

Receiving Party” has the meaning given to it in Clause 22.1.

Refrigerant Losses Performance Guarantee” means the loss in Mixed Refrigerant from compressor seals on one Liquefaction Train of [***] based on a normal back pressure of [***].

Reliability Guarantee” has the meaning given to it in Clause 25.1(g).

Representatives” means (a) in the case of Buyer, Buyer’s Representatives and (b) in the case of Seller, Seller’s Representatives.

SDN” has the meaning given to it in Clause 16.5(a).

S&P” means Standard & Poor’s Corporation and any successor thereto.

Second LTS Purchase Order” means that purchase order contract for the sale of liquefaction train system described therein to be entered into by Seller and Buyer in accordance with the terms of the Letter of Agreement in relation to the second phase of the LNG export terminal and liquefaction project to be located at the Site.

Seller” means Baker Hughes Energy Services LLC, together with its successors and permitted assigns, who shall sell and deliver the Liquefaction Trains under the Agreement.

Seller Competitors” means [***] or any of their respective Affiliates and any other entities that are competitors of Seller [***], as Buyer and Seller may agree from time to time.

Seller Developed Intellectual Property” has the meaning given to it in Clause 18.3.

 

A-11


Seller Excluded Parties” means Seller and its Affiliates and all of their respective directors, officers, assigns and employees and Seller’s Approved Subcontractors, and General Electric Company and each of its subsidiaries, owners, shareholders and all of their respective directors, officers, assigns and employees.

Seller Parent Company Guarantee” means the guarantee dated February 26, 2021 issued by Seller’s Guarantor to Buyer in accordance with Clause 7.9.

Seller’s Guarantor” means Baker Hughes Holdings LLC, a Delaware limited liability company.

Seller’s Know-How” means all of the information, technique and/or know-how related to the design, engineering, manufacturing, construction, operation, maintenance, optimization, repair and servicing of the Liquefaction Train System which was owned by Seller prior to the Agreement or acquired by Seller during performance of the Agreement.

Seller Parties” means Seller and its Affiliates and all of their respective directors, officers, agents, advisors, engineers, contractors, consultants, representatives, assigns, employees and any other Person acting on behalf of any of them or in representation, interest, benefit thereto.

Seller’s Representatives” has the meaning given to it in Clause 22.1.

Seller Taxes” means any and all existing or future (a) corporate and personal income taxes imposed on Seller and its employees by the applicable Laws of any country and (b) taxes, Duties, fees, or other charges of any nature (including, but not limited to, ad valorem, consumption, excise, franchise, gross receipts, import, export, license, property, sales and use, stamp, storage, transfer, turnover, or value-added taxes, or other similar taxes, and any and all items of deficiency, penalty, addition to tax, interest, or assessment related thereto), imposed by any Governmental Authority of any country, other than the United States of America (or any political subdivision thereof), in connection with the execution of the Agreement, Seller’s sale and delivery of the Liquefaction Trains or Seller’s performance of its other obligations under the Agreement.

Serial Defect” has the meaning given to it in Clause 17.2(c).

Services” means all the services to be provided under the attendant and separate Services Agreement.

Services Agreement” means the field services agreement between Buyer, or Owner, and the Services Provider to be entered into on or before Financial Closing under which the Services Provider will for commercially reasonable market based rates provide Buyer, or Owner, with technical field services, training, the on-Site supervision of the installation, start-up, commissioning and testing of the Liquefaction Trains and the oversight of the operation and maintenance of the Liquefaction Trains that commence commercial operations prior to the Substantial Completion of the Facility.

Services Provider” means Seller or Seller’s Affiliate that provides the Services under the Services Agreement.

 

A-12


Site” means the site located in Plaquemines Parish, Louisiana, as further described in Appendix C (Scope of Supply & Project Schedule).

Spare Parts” has the meaning given to it in Clause 13.3.

Subcontractor” means any Person to whom any part of Seller’s obligations under the Agreement has been subcontracted to by Seller.

Substantial Completion of the Facility” means “Facility Substantial Completion” as defined in the EPC Agreement.

Substantial Completion of the Liquefaction Train” means that the Liquefaction Train (i) has achieved Ready for Test, (ii) has completed the Liquefaction Train Performance Tests and (iii) either (1) has satisfied all Liquefaction Train Performance Guarantees or (2) has satisfied the Liquefaction Train Power Demand Minimum Performance Guarantee and Seller has paid all payable liquidated damages for the Liquefaction Train Performance Guarantees that were not met.

Substantial Completion of the Liquefaction Train System” means that the Liquefaction Train System (i) has achieved Ready for Test, (ii) has completed the Liquefaction Train System Performance Tests and (iii) either (1) has satisfied all Liquefaction Train System Performance Guarantees or (2) has satisfied the Liquefaction Train System Power Demand Minimum Performance Guarantee and the Refrigerant Losses Performance Guarantee and Seller has paid all applicable liquidated damages for the Liquefaction Train System Performance Guarantees that were not met.

Technical Documentation” means all technical documentation, specifications, samples, patterns, models, calculations, computer programs (software), Operation And Maintenance Manuals and other documents or information of a similar nature, to be submitted by Seller to Buyer in native files, in accordance with Clause 18, and .PDF in accordance with Appendix C (Scope of Supply & Project Schedule). A list of files required to be submitted in native format is set forth in Appendix C (Scope of Supply & Project Schedule).

Termination Fee” has the meaning given to it in Clause 29.2.

Tonne” means metric ton and is defined as 2204.6 lbs.

Transportation Costs” has the meaning given to it in Clause 7.1.

Unconditional Performance Obligation” means Seller’s absolute obligation to achieve (a) the Liquefaction Train Production Capacity Performance Guarantee for each and every Liquefaction Train, (b) the Liquefaction Train System Production Capacity Performance Guarantee, (c) the LNG Quality Performance Guarantee, (d) the Minimum Performance Guarantees and (e) the Reliability Guarantee.

 

A-13


Vessel Reservation Agreement” means the letter agreement dated as of September 30, 2020 between Seller and VGLNG relating to the reservation of ocean vessels for transportation of portions of the Liquefaction Trains, as supplemented by letter agreement dated as of May 27, 2021 and letter agreement dated as of June 17, 2021.

VGLNG” has the meaning given to it in the recitals of the Agreement.

Warranty Period” means the period, specified as such in Clause 17.1.

Week” means a calendar week consisting of seven (7) Days.

Working Day” means any Day other than a Saturday, or a Sunday or a legal holiday in the State of New York (solely for the purpose of a payment obligation) or the State of Louisiana (with respect to all other obligations).

Work Product” has the meaning given to it in Clause 18.1.

 

1.2

Interpretation

In the Agreement, unless the context otherwise requires or the relevant provision(s) expressly state otherwise:

 

  (a)

the headings to the clauses and the emphasizing are for convenience only and do not affect the interpretation of the Agreement;

 

  (b)

all references to documents or other instruments include all amendments and replacements thereof and supplements thereto;

 

  (c)

all references to any statute or statutory provision shall include references to any statute or statutory provision which amends, extends, consolidates or replaces the same or which has been amended, extended, consolidated or replaced by the same and shall include any orders, regulations, instruments or other subordinate legislation made under the relevant statute;

 

  (d)

reference to a ‘Person’ or ‘Persons’ or a ‘party’ or ‘parties’ includes individuals, bodies corporate, unincorporated associations and partnership and that Person’s or those Persons’ personal representatives, successors and permitted assignees, private or public bodies or individuals;

 

  (e)

any obligation on a Party to do anything shall be deemed to include an obligation to procure such thing to be done; any obligation not to do anything shall be deemed to include an obligation not to permit or not to suffer such thing;

 

  (f)

when a time-limit is determined in Days, it expires at the end of the last Day and it is counted from Day to Day; when it is determined in Months, it is counted from Day of Month to Day of Month; if the last Day of either time-limit is a public holiday, the time-limit is extended to the end of the first Working Day that follows;

 

A-14


  (g)

save exceptions agreed to by Buyer, the only measurement units admitted are the internationally used measurement units of the metric system;

 

  (h)

if any reference is made in the Agreement to Incoterms or any standards such as ISO standards, the particular Incoterms or standards will apply only:

 

  (i)

to the particular item in respect of which they are used; and,

 

  (ii)

to the extent that such application is not conflicting with the content of the Agreement;

 

  (i)

‘including’ shall, unless expressly stated otherwise, mean ‘including without limitation’;

 

  (j)

references to a ‘Clause’ shall be to a clause of the Agreement;

 

  (k)

the singular number includes the plural number and vice versa;

 

  (l)

reference to any gender includes the other;

 

  (m)

‘hereunder,’ ‘hereof,’ ‘hereto’ and words of similar import shall be deemed references to the Agreement as a whole and not to any particular Clause or other provision hereof or thereof;

 

  (n)

the term ‘or’ is not exclusive, regardless of whether ‘and/or’ is used in the applicable provision; and

 

  (o)

if the Buyer assigns the Agreement to the EPC Contractor, all references to “Buyer” hereunder shall be treated as a reference to “EPC Contractor”, and if Buyer does not assign this Agreement to the EPC Contractor, each reference to “Buyer” hereunder shall be treated as a reference to “Owner”.

 

1.3

Communications - Notices

Any notice, instruction, consent, approval, comment, certificate or determination to be given in connection with the Agreement shall be effective only if in writing and addressed to the Person, as each Party or Owner has identified below: (a) on delivery, if delivered personally to the Person; (b) on transmission, if transmitted to the facsimile number of the Person or by electronic mail; and (c) on posting, if by first class or overnight mail (postage prepaid). No change of address for a Party or Owner shall be effective until written notice of the change of address is provided to the other Parties and Owner in accordance with this Clause 1.3.

If to Buyer: [***]

 

A-15


If to Seller: [***]

If to Owner: [***]

 

A-16


1.4

Language

 

  (a)

All correspondence between Buyer and Seller as well as all Technical Documentation and comments thereto and shipping marks shall be in English.

 

  (b)

The Operation and Maintenance Manuals, all markings on equipment, labels, sign-boards, instrument dials, graphical interfaces with the process control system, safety documentation, machine and component name plates shall be in English.

 

1.5

No Joint Venture, Partnership or Association

 

  (a)

The Agreement shall not be interpreted or construed to create an association, joint venture, or partnership between the Parties or to impose any partnership obligation or liability upon either Party.

 

  (b)

Neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.

 

1.6

Parties to act reasonably

 

  (a)

Where reference is made in the Agreement to a Party’s decision, approval, refusal, consent, agreement, act, etc., such shall not be taken, given or withheld unreasonably or unfairly, unless otherwise expressly stated.

 

  (b)

In all cases the Party claiming a breach of the Agreement by the other Party, shall be obligated to make commercially reasonable efforts to mitigate its costs, losses or damages that have occurred or that may occur as a result of such breach.

 

2.

REQUESTS AND CLARIFICATIONS

Seller represents and warrants to Buyer that Appendix C (Scope of Supply & Project Schedule) includes all of the necessary obligations that are required to be performed by Seller in order for the Liquefaction Train System to operate in accordance with the requirements of the Agreement and satisfy the design codes, standards and the Performance Guarantees set forth in the Agreement. The Parties acknowledge and agree that Appendix C (Scope of Supply & Project Schedule) describes the items for the Liquefaction Train System being provided in general, but not in complete detail. The Parties agree that any

 

A-17


specific items not set forth in Appendix C (Scope of Supply & Project Schedule), or any details or clarifications thereto, that are required in order to satisfy the requirements of the Agreement or to satisfy the design codes, standards and the Performance Guarantees set forth in the Agreement, in each case, will not be considered changes to Appendix C (Scope of Supply & Project Schedule), unless they are explicitly excluded from Appendix C (Scope of Supply & Project Schedule), or are changes to the Basis of Design directed by Buyer, or changes pursuant to the Change Order requirements of Clause 24, and Seller waives any right to adjust the Contract Price or the Project Schedule with respect thereto. The Parties acknowledge and agree that Appendix C (Scope of Supply & Project Schedule) contains certain single-line diagrams, pipe and instrumentation diagrams and other diagrams and drawings that will change as Seller completes its engineering of the Liquefaction Train System and that any change to such diagrams and drawings, which are not the result of changes to the Basis of Design directed by Buyer, or changes pursuant to the Change Order requirements of Clause 24, will not be changes that will entitle either Party to changes in the Contract Price or an extension of the Project Schedule.

Buyer may issue to Seller requests or non-material clarifications that are not inconsistent with the obligations of Seller under Appendix C (Scope of Supply & Project Schedule) which Buyer may consider necessary or helpful to Seller in the performance of Seller’s obligations under the Agreement. Seller will evaluate Buyer’s requests or clarifications within a reasonable time period and provide feedback in writing to Buyer. Seller agrees to cooperate with Buyer’s other contractors, including the EPC Contractor.

In the event any such request or clarification of Buyer is transmitted orally, Seller may require Buyer to confirm such request or clarification in writing. Seller shall notify Buyer of such requirement to confirm in writing without undue delay but in any event within seven (7) Working Days of receipt of Buyer’s verbal transmission. If Seller has requested such written confirmation, the request or clarification shall not be effective until written confirmation thereof has been received by Seller.

Any such request or clarification from Buyer shall not relieve Seller from its responsibility for delivering the Liquefaction Trains and performing its other obligations in accordance with the Agreement.

Seller and Buyer agree to reasonably cooperate and work together in good faith with the shared objective of using the experience, knowledge and data derived from the performance under the Agreement and the Calcasieu Purchase Order to optimize the project management services, engineering services, procurement, manufacturing and performance of the Liquefaction Train System in combination with the balance of plant of the Facility (excluding BH improvements that are unrelated to and do not impact the performance, reliability or maintenance of the Liquefaction Train System) with the common goals of (a) increasing the operational performance of the Liquefaction Train System and (b) if possible and solely to the extent consistent with clause (a), reducing the Contract Price; provided, however, that Seller and Buyer acknowledge that (i) no particular result is assured or guaranteed from such price optimization efforts and (ii) Seller shall not be permitted to change the means and methods of its performance or the Basis of Design:

 

A-18


(1) in a manner that would deny or reduce the value to Buyer of the benefits of the optimization of the performance of the Liquefaction Train System achieved by Buyer or (2) except as contemplated under Clause 6.6, without the prior written approval of Buyer. Prior to implementation, Buyer shall consult with Seller in respect of any modifications that adversely and materially impact the inlet, exit or throughput conditions of the Liquefaction Train System. Notwithstanding the foregoing, if and to the extent that Seller makes adjustments to its means and methods or design specifications under the Calcasieu Purchase Order after the Effective Date that relate to Seller achieving the performance guarantees set forth in the Calcasieu Purchase Order, such adjustments may be incorporated into the Agreement.

 

3.

PROJECT DIRECTOR

Seller shall provide all oversight and superintendence that is necessary for the performance of its obligations, and obligations of its personnel and the personnel of its Subcontractors, under the Agreement. Pursuant to Clause 3 of the Original Purchase Order, Seller appointed a project director, who shall act as a competent and authorized representative of Seller and devote the necessary time to the oversight and superintendence of the same and who shall have the authority to act on Seller’s behalf under the Agreement and receive, on behalf of Seller, requests or clarifications from Buyer. In addition, to the extent that such persons are still employees of Baker Hughes Company, then Seller shall make available to Buyer for the performance of this Agreement the same senior supervisory personnel that are presently engaged with Venture Global Calcasieu Pass, LLC in respect of the liquefaction trains under the Calcasieu Purchase Order. The replacement of, or additions to, the Key Personnel shall only be made with persons having qualifications and experience comparable to those being replaced or added to. In connection with any substitution of Key Personnel, Buyer shall (a) include a detailed explanation and reason for the request and the resumes of professional education and experience for a minimum of two (2) candidate(s) of suitable qualifications and experience and (b) discuss such candidates in advance with Buyer in order to allow Buyer to provide feedback and request for clarifications. Seller shall use commercially reasonable efforts to take Buyer’s recommendations into consideration. In addition, Buyer may if it is concerned with the performance of any Key Personnel request the removal of, and Seller shall use commercially reasonable efforts to comply with such request to remove and replace, such Key Personnel; provided that if Buyer reasonably demonstrates that such Key Personnel has: (i) been gravely incompetent or negligent in the performance of his or her duties, or (ii) engaged in activities in material violation of the Law or of any safety and security protocols of Buyer that were communicated to Seller in writing, Seller shall promptly remove such Key Personnel and replace such Key Personnel in accordance with this Clause 3.

 

A-19


4.

ASSIGNMENT AND SUBCONTRACTING

 

4.1

Assignment

Buyer shall not transfer or assign the Agreement or any of its rights under or interest in the Agreement (including monies that are due or monies that may be due) without the prior written consent of Seller, which consent shall not be unreasonably withheld, conditioned or delayed; provided, however, that Buyer shall not need the consent of Seller (a) to transfer or assign the Agreement to its Affiliate (to the extent such Affiliate is organized under the laws of the United States of America), (b) to transfer or assign the Agreement to the EPC Contractor subject to the requirements under this Clause 4.1 or (c) to assign, charge or otherwise encumber the Agreement or any rights or benefits arising thereunder or therefrom by way of collateral in favor of Lenders. Seller may only transfer or assign the Agreement or any of its rights under or interest in the Agreement (including monies that are due or monies that may be due) with the prior written consent of Buyer, which consent shall not be unreasonably withheld, conditioned or delayed; provided, however, that Seller shall not need the consent of Buyer to assign or novate the Agreement to any Affiliate of Seller that is ultimately wholly owned by Baker Hughes Company and assign any receivables due Seller hereunder to one (1) or more Affiliates of Seller or to third parties. The Parties agree to execute such documents as may be necessary to effect any permitted assignments or transfers of the Agreement. In connection with any collateral assignment of the Agreement by Buyer, Seller shall provide any customary agreements, certificates, legal opinions or other documents reasonably required by any Lender. In connection with any assignment of the Agreement to the EPC Contractor by Buyer, Seller shall agree to any modifications to the Agreement that are reasonably requested by the EPC Contractor, so long as such modifications do not impose any additional risk, costs, expenses or liability on Seller or Owner. In the event of a transfer or assignment of the Agreement by (i) Buyer, (A) Buyer’s assignee or transferee shall have financial capabilities, directly or by virtue of credit enhancements or other financial arrangements, that are comparable or better than Buyer’s, as of the Effective Date, and (B) Buyer shall cause the credit support under Clause 7.8 to be maintained or provide Seller with replacement credit support that is reasonably acceptable to Seller and substantially similar as provided to Seller hereunder (in which case, if the conditions of Clause 4.1(i)(A) and (i)(B) are met, any credit support that was provided to Seller prior to such assignment shall be promptly returned by Seller to Buyer) and (ii) Seller, Seller shall cause the credit support under Clause 7.9 to be maintained or provide Buyer with replacement credit support that is reasonably acceptable to Buyer and substantially similar as provided to Buyer hereunder. Any assignment, novation, transfer or other disposal in violation of this Clause 4.1 shall be null and void ab initio and shall not be binding on the Parties. For any assignment by Buyer of the Agreement either to Affiliates, EPC Contractor or any other third parties, Buyer acknowledges that Seller shall perform its standard “Know Your Customer” due diligence (which involves various compliance and financial due diligence) on the proposed assignee and the proposed assignee must satisfy the “Know Your Customer” requirements.

 

A-20


4.2

Subcontracting

Seller and Buyer agree that Seller may not utilize the services of any Subcontractors without obtaining Buyer’s prior written approval, which approval may not be unreasonably delayed or withheld. As of the Effective Date, Buyer has agreed that Seller may, subject to the remaining provisions of this Clause 4.2 and Clause 8.4, utilize the services of the Approved Subcontractors listed in Appendix G (Approved Subcontractors). Seller may only utilize the services of the Approved Subcontractors (a) that satisfy Buyer’s quality requirements and (b) in accordance with the requirements set forth in this Clause 4.2. If Seller is considering utilizing the services of any Subcontractor that is not an Approved Subcontractor, then Seller shall notify Buyer of its proposal for such Subcontractor to become an Approved Subcontractor and furnish to Buyer all information reasonably requested by Buyer with respect to the qualifications of such proposed Subcontractor. Buyer shall have the right, acting reasonably, to reject any such proposed Subcontractor, and Seller shall not enter into any subcontract with such proposed Subcontractor that is rejected by Buyer. If an Approved Subcontractor, that has been selected to provide or is providing equipment, becomes subject to bankruptcy or insolvency proceedings or is unable, in Seller’s reasonable judgment, to supply all of the relevant equipment due to capacity constraints, Seller and Buyer will collaborate to develop a list of three or fewer acceptable Subcontractors to replace or supplement such Approved Subcontractor, and shall amend Appendix G accordingly. If Buyer rejects such proposed Subcontractor and the existing Approved Subcontractors are not acceptable in Seller’s reasonable determination for price, quality or schedule reasons, then Seller shall be entitled to a Change Order for any resulting incremental increase in price or delay in the Delivery Date as a result of Buyer’s rejection of such proposed Subcontractor. Approval of any Subcontractor under this Clause 4.2 shall only be for the portion of Seller’s obligations so approved by Buyer. No subcontract with an Approved Subcontractor shall bind or purport to bind Buyer, but each such subcontract shall contain a provision permitting its assignment to Buyer, Owner or the Lenders upon Buyer’s or Seller’s written request.

Seller acknowledges and agrees that Buyer shall have the right to consent to and approve the supplier of each major component of equipment comprising the Liquefaction Train System, [***] (each a “Major Component”), and confirms the strategy to use the same Approved Subcontractor identified on Appendix G for each item, as identified by its specific Tag Number, for all Liquefaction Trains. To assist Buyer in the selection of Major Components, for each potential vendor or supplier of a Major Component, Seller agrees to provide Buyer with access to: (a) the identity of the potential vendor or supplier; (b) the delivery and schedule terms for the Major Component; (c) in the case of the Cold Boxes and heat exchangers, the price negotiated by Seller for such Major Components; and (d) all technical and performance information for each Major Component requested by Buyer. To the extent a Major Component supplier is changed based on a Buyer directive and, as a result of such change in Major Component supplier, Seller incurs a documented incremental increase in the price of the Major Component or delay in the delivery of the Major Component that adversely affects the Delivery Date, Seller shall be entitled to a Change Order for an equitable adjustment in the Contract Price and the Project Schedule for the applicable Liquefaction Train System. To the extent that Seller obtains a discount or reduced purchase price from the supplier of Cold Boxes, Seller agrees to pass such

 

A-21


discount or savings on to Buyer through a reduction in the Contract Price, except to the extent such discount or reduced purchase price results from a material change in the terms and conditions between Seller and such supplier of Cold Boxes that is adverse to Seller. No such discount or material change shall result in a reduction in the quality or capability of performance of the Liquefaction Train System.

Seller further acknowledges that it shall notify Buyer before subcontracting with any Major Subcontractor (excluding for the avoidance of doubt any Approved Subcontractor) supplying materials or fabrication services in connection with the performance of this Agreement that is located in Asia. Buyer shall have the right to reject any such Major Subcontractor so long as a reasonably comparable subcontractor located outside of Asia is identified as capable of performing the relevant scope of supply, and in such event Seller shall not enter into a subcontract with the Asia-based entity. If Buyer has rejected such proposed Major Subcontractor and the comparable subcontractor located outside of Asia that was identified as capable of performing the relevant scope of supply is not acceptable, in Seller’s reasonable determination, for price, quality or schedule reasons (with Seller having validated for Buyer its determination as to such comparable subcontractor), then, unless such comparable subcontractor is an Approved Subcontractor, Seller shall be entitled to a Change Order for any resulting incremental and documented increase in the Contract Price or adjustment to the Project Schedule, in each case as a result of Buyer’s rejection of such proposed Major Subcontractor.

 

4.3

Other

 

  (a)

Seller hereby acknowledges and agrees that the review or acceptance of any contract between Seller and an Approved Subcontractor by Buyer and the acceptance of the Approved Subcontractors shall not: (i) modify or relieve, in any way, the obligations of Seller pursuant to the Agreement; (ii) be raised as a claim or as a defense or counterclaim to any claim in connection with the Agreement; or (iii) constitute any approval or acceptance of the work, services or equipment provided under such subcontract or by such Approved Subcontractor.

 

  (b)

At a minimum, all contracts between Seller and an Approved Subcontractor shall require the following:

 

  (i)

such Approved Subcontractor shall comply with all applicable professional standards, permits and Laws, rules, codes and regulations and with the performance standards of Seller under the Agreement;

 

  (ii)

Buyer and Owner shall have all the inspection rights that Buyer and Owner have under the Agreement;

 

  (iii)

such Approved Subcontractor shall be subject to the applicable labor obligations and the safety and security provisions under the Agreement;

 

A-22


  (iv)

such Approved Subcontractor shall provide guarantees and warranties with respect to the work and services performed and the materials provided under such contract;

 

  (v)

such Approved Subcontractor shall (A) obtain and carry the insurance coverages (with limits appropriate to the value of such contract) required of Seller pursuant to Clause 23 from an insurance carrier with an A rating from A.M. Best and naming Buyer as an “additional insured”, and (B) provide certificates of insurance as set forth herein;

 

  (vi)

such contract shall be subject to the dispute resolution procedures as set forth herein;

 

  (vii)

such Major Subcontractor(s) shall provide the applicable Lien waiver and releases required under Clause 7.6, in connection with each payment to Seller hereunder;

 

  (viii)

such Approved Subcontractor(s) shall grant a license to Buyer in accordance with Clause 18.1 and Clause 18.3;

 

  (ix)

such contract shall be subject to the confidentiality provisions set forth under the Agreement; and

 

  (x)

such contract shall be subject to the anti-corruption provisions set forth in Clause 16.5.

 

  (c)

All contracts between Seller and an Approved Subcontractor must specify that the contractual relationship with such Approved Subcontractor is exclusive to Seller and that such Approved Subcontractor waives any and all rights to demand any payment directly from Buyer and Owner. All contracts between Seller and Approved Subcontractors shall preserve and protect the rights of Buyer and Owner, shall not prejudice such rights and shall require each Approved Subcontractor to enter into similar agreements with its subcontractors. As between Seller and Buyer, Seller shall be solely responsible for the acts, omissions or defaults of the Approved Subcontractors and their agents, representatives and employees. Nothing in the Agreement shall be construed to impose on Buyer or Owner any obligation, liability or duty to an Approved Subcontractor or any other Subcontractor or to create any contractual relationship between any Subcontractor, including any Approved Subcontractor, or other third party and Buyer, including an obligation to pay or to see to the payment of any moneys due any such Subcontractor, Approved Subcontractor or other third party.

 

  (d)

No Approved Subcontractor is intended to be nor shall be deemed a third party beneficiary of the Agreement. In addition to the requirements set forth above, Seller shall include in each contract with an Approved Subcontractor language under which Buyer and Owner shall be made express third party beneficiaries of

 

A-23


  such contract. If any Approved Subcontractor or proposed Subcontractor refuses to name Buyer and Owner as a third party beneficiary or provide for a right of assignment to Buyer, then Seller shall not use such Subcontractor for any portion of Seller’s obligations hereunder, unless Buyer’s prior written consent is obtained.

 

  (e)

Contingent upon receipt of Buyer’s designation in writing as set forth below, Seller hereby assigns to Buyer (and Buyer’s permitted assigns) all its interest in any contracts with Approved Subcontractors (or any portion thereof to the extent such contracts also relate to other projects of Seller) now existing or hereafter entered into by Seller for performance of any part of the work or services, or provision of any materials under the Agreement. Such assignment of Approved Subcontractor contracts will be effective upon written acceptance by Buyer in writing and only as to those contracts which Buyer designates in such written acceptance.

 

5.

SCOPE

Seller agrees to have the Liquefaction Modules manufactured at Seller’s Affiliate’s manufacturing facilities located in [***] , and to sell and deliver the Liquefaction Trains and provide the associated Technical Documentation to Buyer as set forth in Appendix C (Scope of Supply & Project Schedule) by the respective Delivery Dates, all in compliance with all other obligations under the Agreement. If Seller’s planned expansion of the manufacturing facilities located in [***] described in this Clause 5 is not completed, is suspended or is otherwise delayed as a result of delays and other issues in obtaining any required permits, authorizations, licenses and approvals from Governmental Authorities, Seller is entitled to an equitable adjustment to the applicable Delivery Date(s) with respect to the last six (6) Liquefaction Trains set forth in the Project Schedule, but not to exceed [***].

 

6.

COMPLIANCE WITH TIME-LIMITS

 

6.1

Time for delivery

Seller shall diligently proceed with the performance of its obligations under the Agreement in accordance with the Project Schedule and the other requirements of the Agreement.

 

6.2

Progress of Works – Delay

Seller shall cause each Liquefaction Train to be delivered on or before the Delivery Date for such Liquefaction Train. If, at any time, Seller’s actual progress with respect to a Liquefaction Train is not consistent with meeting the Delivery Date for such Liquefaction Train, or as from the moment any of Seller’s personnel working on the Liquefaction Train System becomes aware of the fact that a Milestone for a Liquefaction Train cannot be met that will affect the Delivery Date for a Liquefaction Train, Seller shall promptly provide written notice to Buyer of such occurrence and shall develop, a recovery plan to overcome the anticipated delay and provide to Buyer, within ten (10) Working Days of such occurrence, a report identifying:

 

  (a)

the likely period of delay;

 

  (b)

the event causing the delay;

 

A-24


  (c)

the impact which such event has had or in the opinion of Seller is likely to have or will have on its ability to achieve any of the Milestones;

 

  (d)

the recovery plan developed by Seller to overcome the anticipated delay and the steps which Seller has taken, is taking and will take to mitigate the adverse consequences of such event; and

 

  (e)

further particulars of the consequences of the delay as Seller becomes aware.

Seller shall, in consultation with Buyer, implement the recovery plan and use best efforts to minimize or remove the actual or anticipated delay and any consequences thereof. If Buyer provides notice to Seller that Buyer reasonably believes that the steps proposed by Seller fail to adequately address the anticipated delay in meeting the Milestones as part of the recovery plan developed by Seller, then Seller shall increase its efforts in order to remove or minimize such anticipated delay.

 

6.3

Restriction on Change Order for Extension of Delivery Date

Seller shall not be entitled to a Change Order for an extension of time under the Agreement and/or reimbursement of Costs to the extent that such extension or reimbursement is due to any act, omission or default on the part of Seller or any Subcontractor.

 

6.4

Delivery Delay Liquidated Damages

 

  (a)

Each Liquefaction Train and certain Deliverables have a Delivery Date. If Seller fails to deliver a Liquefaction Train or such Deliverable by its associated Delivery Date, as the Delivery Date may be extended according to a Change Order, Seller shall be obligated to pay to Buyer liquidated damages (the “Delivery Delay Liquidated Damages”) for delay in achieving the Delivery Date as from the first Day following the scheduled Delivery Date until the Day on which delivery of (i) that specific Liquefaction Train to the Delivery Point actually occurs, provided that Seller shall not be obligated to pay Delivery Delay Liquidated Damages for any Day (or part thereof) beyond [***] that is required for a Liquefaction Train to clear U.S. customs for reasons that are not attributable to Seller’s or its Subcontractors’ acts or omissions or (ii) that specific Deliverable to Buyer actually occurs.

 

  (b)

The Delivery Delay Liquidated Damages payable by Seller to Buyer for each Day of delay in delivery of a specific Deliverable to Buyer beyond the Delivery Date for such Deliverable is [***] per Day. The aggregate amount of the Delivery Delay Liquidated Damages payable by Seller to Buyer for all Deliverables shall not exceed [***] .

 

A-25


  (c)

For each Liquefaction Train, the liquidated damages payable by Seller to Buyer for each Day of delay in delivery of the specific Liquefaction Train (in its entirety) to the Delivery Point beyond the Delivery Date is (i) in respect of the first [***] Liquefaction Trains to be delivered, an amount equal to: (1) for each of the first [***] Days of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days; (ii) in respect of the subsequent [***] Liquefaction Trains, an amount equal to: (1) for each of the first [***] Days of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days.

 

  (d)

The aggregate amount of Delivery Delay Liquidated Damages payable by Seller to Buyer for (i) each Liquefaction Train shall not exceed the applicable Delivery Delay Liquidated Damages Cap, and (ii) all Liquefaction Trains shall not exceed the Aggregate Delivery Delay Liquidated Damages Cap. Liquidated Damages payable by Seller to Buyer shall not exceed the Liquidated Damages Cap. Once Seller has accrued Delivery Delay Liquidated Damages in an amount equal to the Delivery Delay Liquidated Damages Cap or Aggregate Delivery Delay Liquidated Damages Cap, as applicable, Buyer shall be entitled to exercise the rights provided in Clause 6.5.

 

  (e)

Buyer shall invoice Seller for any amounts due for Delivery Delay Liquidated Damages. Payment of any Delivery Delay Liquidated Damages shall occur by Seller within [***] following the date Buyer submits to Seller an invoice therefore. Buyer and Seller agree that the amount of Delivery Delay Liquidated Damages are reasonable in light of the anticipated harm caused by the breach of duty related thereto and the difficulties of proof of loss and inconvenience or non-feasibility of obtaining any adequate remedy with respect to the actual level of damages Buyer is likely to suffer as the result of a Delivery Delay Event, and the Parties are estopped from contesting the validity or enforceability of such liquidated damages. Except as provided in Clause 28.1 and Clause 28.3, the payment of Delivery Delay Liquidated Damages during the period prior to the Delay Limit Date shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for any Delivery Delay Event. In the event the Delivery Delay Liquidated Damages provisions in the Agreement are found for any reason to be void, invalid or otherwise inoperative so as to disentitle Buyer from claiming and recovering Delivery Delay Liquidated Damages from Seller for any Delivery Delay Event, Buyer shall, in addition to the remedies set forth below in Clause 6.5, be entitled to claim against Seller and recover for damages for any Delivery Delay Event; provided that such damages shall not exceed the limitations set forth in Clause 6.4(d).

 

A-26


6.5

Delays - Other remedies

Notwithstanding Clause 6.2, if Seller has reached the Delay Limit Date, Buyer may by notice to Seller, at Buyer’s sole discretion:

 

  (a)

require Seller to agree, within [***] of Buyer’s demand, to remedy the Delivery Delay Event, within the period of time identified by Buyer, at Buyer’s sole discretion. If Seller fails to agree within [***] of Buyer’s demand, or fails to remedy the Delivery Delay Event within such agreed period(s), Buyer shall be free to exercise its rights or remedies under clause (b) hereafter; or

 

  (b)

terminate the Agreement in accordance with Clause 28.1(g) and seek to recover from Seller Buyer’s damages pursuant to Clause 28.3 (subject to the limit of liability cap in Clause 19.2) arising from the applicable Delivery Delay Event, and, upon such termination by Buyer, Seller shall deliver to Buyer the portions of the Liquefaction Train System for which Seller has received payment and which have not been delivered to the Delivery Point; provided, however, that Buyer shall not be entitled to terminate the Agreement for so long as Seller continues to pay Buyer the applicable Delivery Delay Liquidated Damages, despite the fact that the aggregate amount of Delivery Delay Liquidated Damages paid by Seller have exceeded the limitations set forth in Clause 6.4(d).

 

6.6

Issuance of LNTP and FNTP

The Project Schedule assumes that a limited notice to proceed (“LNTP”) authorizing the LNTP scope described in Appendix B (Pricing, Payment Terms & Cancellation Schedule) and Appendix C (Scope of Supply & Project Schedule) will be issued by Buyer no later than [***] Days prior to the issuance of the full notice to proceed authorizing Seller to proceed with the full scope of work under the Agreement (“FNTP”). If the LNTP is issued less than [***] Days prior to the issuance of the FNTP, the Project Schedule shall be extended day for day for each day that the LNTP was issued less than [***] Days prior to the issuance of the FNTP. Seller and Buyer acknowledge and agree that: (a) LNTP No. 1 was issued by Buyer pursuant to Clause 6.6 of the Original Purchase Order on September 30, 2021 and that LNTP No. 1 shall be considered the LNTP referenced in this Clause , 6.6; (b) the amount payable under LNTP No. 1 was originally [***] and such amount is hereby increased to [***]; (c) [***] of such amount was paid in full prior to the Effective Date as a result of the LNTP Advance; and (d) a total of [***] of the LNTP Advance has been applied by VGLNG pursuant to the Vessel Reservation Agreement and this amount represents a portion of the Transportation Costs set forth in Clause 7.1 of Appendix A (General Terms & Conditions) to the Agreement. If Buyer fails to issue the FNTP on or prior to [***], the senior management of Buyer and Seller shall meet within ten (10) Days

 

A-27


thereafter to discuss when, if at all, the FNTP will be issued. If, after the senior management meeting there is no mutual agreement on extending the time for issuance of the FNTP, either Buyer or Seller may terminate the Agreement in which case Buyer shall pay Seller the applicable Termination Fee. Buyer may issue additional LNTPs for scope beyond what is provided in Appendix C (Scope of Supply & Project Schedule) pursuant to a Change Order issued pursuant to Clause 24.1.

 

6.7

Delivery Bonus

If Seller delivers a Liquefaction Train to Buyer at the Delivery Point on or before the date that is [***] Days prior to the relevant Delivery Date for such Liquefaction Train in the Project Schedule, then Buyer shall pay to Seller an amount equal to (i) in respect of the first [***] Liquefaction Trains, [***] for each such Liquefaction Train delivered to the Delivery Point prior to the Delivery Date provided for such Liquefaction Train, and (ii) in respect of the subsequent [***] Liquefaction Trains, [***] for each such Liquefaction Train delivered to the Delivery Point prior to the Delivery Date provided for such Liquefaction Train, each of which amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement; provided, that in no event shall the total aggregate amount of all bonus amounts paid by Buyer under this Clause 6.7 exceed [***] . For the purposes of this Clause 6.7 only, Seller shall be deemed to have delivered any Liquefaction Train described in this Clause 6.7 that is delivered to Buyer at the Delivery Point on or before the date that is at least [***] prior to the relevant Delivery Date for such Liquefaction Train in the Project Schedule notwithstanding that certain minor items forming a part of the Liquefaction Train have not been delivered to Buyer at the Delivery Point by such date; provided that (i) the Lender’s Engineer has confirmed to Buyer in writing (upon Buyer’s request) that the absence of such minor items would not reasonably be expected to adversely impact the project schedule for testing, commissioning, safety or operability of such Liquefaction Train and (ii) all such minor items are delivered to Buyer at the Delivery Point not later than the relevant Delivery Date for such Liquefaction Train in the Project Schedule or such other date as mutually agreed by the Parties in writing. Amounts earned by Seller pursuant to this Clause 6.7 shall be due and payable by Buyer to Seller upon the completion of delivery by Seller of all Components (as such term is defined in the PIS Purchase Order) of the power island system in accordance with the PIS Purchase Order.

 

7.

CONTRACT PRICE AND PAYMENT

 

7.1

Definition of Contract Price

The Contract Price is equal to the sum of [***].

The Contract Price, payment terms and cancellation schedule/charges for each individual Liquefaction Train is detailed in Appendix B (Pricing; Payment Terms & Cancellation Schedule). The Contract Price shall not include any duties and tariffs paid by Seller to deliver each Liquefaction Train to the Delivery Point (“Duties”) or the physical

 

A-28


transportation costs set forth in Appendix K (Transportation Costs), exclusive of insurance costs and taxes associated with physical transportation costs other than Duties for each such Liquefaction Train (“Transportation Costs”). Buyer shall reimburse Seller for all reasonable, documented out-of-pocket Duties and Transportation Costs incurred by Seller, plus a fixed fee of [***], payable in accordance with Appendix B (Pricing; Payment Terms & Cancellation Schedule). The Contract Price does not include any Buyer Taxes. Transportation Costs, inclusive of the fixed fee, shall not exceed in the aggregate an amount equal to the sum of [***] and the amount of the option payment made in 2021 pursuant to the Vessel Reservation Agreement, provided that Seller has made commercially reasonable efforts to obtain competitive transportation pricing terms and to minimize transportation costs. Buyer hereby agrees to pay the Contract Price to Seller upon completion of the relevant Payment Milestones in accordance with the payment schedule (the “Payment Schedule”) set forth in Appendix B (Pricing; Payment Terms & Cancellation Schedule), in consideration for the performance by Seller of its related obligations under the Agreement.

Payment of undisputed amounts of the Contract Price owed to Seller shall be made by Buyer thirty (30) Days from Buyer’s receipt of an invoice from Seller following completion of the relevant Payment Milestone(s) and receipt of all the relevant documentation, in accordance with the Agreement, and shall be remitted by wire transfer to the following account: [***]

 

7.2

Currency

Except as otherwise provided in the Agreement, payment shall be made by Buyer in Dollars, upon the completion of the individual Payment Milestones as set out in the Agreement and after Buyer’s receipt of an invoice for such Payment Milestones, reasonable evidence of the completion of such Payment Milestones, Lien waiver and releases in accordance with Clause 7.6, and other specified documentation required under the Agreement.

 

A-29


7.3

Late Payments

Any undisputed amounts due and unpaid by either Party to the other Party shall bear interest commencing when such payment is due at a rate equal to the lesser of (a) [***] above the per annum Prime Rate reported daily in The Wall Street Journal, or (b) the maximum rate permitted by applicable Law, on all amounts not timely paid in accordance with the Agreement. The payment of interest is in addition, and not in lieu, of a Party’s right to suspend its performance or terminate the Agreement, as provided for under the Agreement.

 

7.4

Payment of Subcontractors

Seller shall pay each Subcontractor, save for disputes between Seller and any Subcontractor, the amount to which Subcontractor is entitled in accordance with the terms and conditions of the Agreement between Seller and such Subcontractor.

 

7.5

Set Off Rights

Each Party shall have the right at any time or from time to time, to set off against any amount due to the other Party under the Agreement any amount due from the other Party under the Agreement, including any amounts due because of breach of the Agreement. Buyer may, after written notice to Seller, withhold payment on an invoice or a portion thereof in the event of a failure of Seller to perform the Payment Milestone related to the payment being requested under such invoice, until such time as such Payment Milestone has been completed by Seller in accordance with the provisions of the Agreement. The written notice to Seller shall reasonably describe the failure of Seller and requirements necessary under the Agreement to complete the Payment Milestone.

 

7.6

Invoice Documentation

As a condition precedent to the obligation of Buyer to make each payment under the Agreement, Seller shall deliver with each invoice for each payment, a partial Lien waiver and release in the form of Appendix J-1 (Seller Form of Partial Lien Waiver and Release) in exchange for the current payment, and a partial Lien waiver and release in the form of Appendix J-3 (Subcontractor Form of Partial Lien Waiver and Release) from each Subcontractor; provided however, if such invoice is the invoice for the final payment under the Agreement, Seller shall be obligated to provide Buyer a final Lien waiver and release in the form of Appendix J-2 (Seller Form of Final Lien Waiver and Release), in exchange for the final payment, and a final Lien waiver and release in the form of Appendix J-4 (Subcontractor Form of Final Lien Waiver and Release) from each such Subcontractor, in exchange for the final payment. In addition to the final Lien waivers and releases from each Subcontractor, Seller shall provide, with such final invoice, an affidavit setting forth:

(a) all amounts paid to each Subcontractor; (b) all amounts owed to each Subcontractor, if any; and (c) any amounts in dispute under any subcontract.

 

A-30


7.7

No Liens

To the extent that Buyer has timely paid Seller under the Agreement, Seller shall (a) not directly or indirectly create, incur, assume, or suffer to be created by it or any Subcontractor, employee, laborer, materialman, or other supplier of goods or services any Liens on or in respect of a Liquefaction Train, the Site, the Facility or any part thereof or interest therein, or against any party, and (b) promptly pay and/or discharge of record any Lien or other charges that, if unpaid, might be or become a Lien on a Liquefaction Train, the Site, the Facility or any part thereof or interest therein. Seller shall pay when due all amounts payable for labor and materials furnished in connection with the Agreement to prevent any Lien or other claim in respect of such labor and materials from arising. Seller shall immediately notify Buyer of the assertion of any Lien on a Liquefaction Train, the Site, the Facility or any part thereof or interest therein. Upon the failure of Seller to promptly pay, discharge, or provide security reasonably acceptable to Buyer for any Lien on a Liquefaction Train, the Site, the Facility or any part thereof or interest therein in respect of which Seller has been timely paid in accordance with the Agreement, within ten (10) Working Days of notice of the existence thereof from any source, Buyer may, but shall not be obligated to, pay or discharge such Lien and, upon the payment or discharge thereof, shall be entitled to immediately recover from Seller the amount thereof together with expenses incurred by it in connection with such payment or discharge or to set off all such amounts against any such sums owed by Buyer to Seller under the Agreement.

 

7.8

Buyer Credit Support

Pursuant to Clause 7.8 of the Original Purchase Order, Buyer provided the Buyer Parent Company Guarantee to Seller. The Buyer Parent Company Guarantee shall remain valid until the earlier of (i) the assignment of the Agreement to the EPC Contractor in accordance with Clause 4 or (ii) Financial Closing, at which time the Buyer Parent Company Guarantee shall be of no further force and effect and Seller shall return the original Buyer Parent Company Guarantee to Buyer. If the Agreement is assigned by Owner to the EPC Contractor, the EPC Contractor (in its capacity as Buyer) will provide to Seller a guarantee substantially in the form of the Buyer Parent Company Guarantee, which guarantee shall remain valid until receipt by Seller of the final payment of the Contract Price.

 

7.9

Seller Credit Support

Pursuant to Clause 7.8 of the Original Purchase Order, Seller provided the Seller Parent Company Guarantee to Buyer.

 

7.10

Payment Not Acceptance

No partial or final payment made by Buyer shall be construed as a waiver of any breach hereof by Seller or as an acceptance of defective portions of the performance by Seller hereunder or of any of the performance of Seller’s obligations hereunder that does not strictly comply with all requirements of the Agreement.

 

A-31


8.

TAXES AND DUTIES

 

8.1

Seller Taxes; Buyer Taxes

Seller shall be responsible for and shall pay all Seller Taxes. Buyer shall be responsible for and shall pay all Buyer Taxes (or reimburse Seller for Buyer Taxes in the event Seller is required to remit any Buyer Taxes directly to taxing authorities). If Buyer deducts or withholds Seller Taxes from the Contract Price, for each deducted or withheld amount of Seller Taxes, Buyer shall provide Seller, within thirty (30) Days from payment of Seller Taxes, with the official receipt issued by the appropriate Governmental Authority to which Seller Taxes have been paid or an alternative document acceptable to the relevant tax authorities. In respect of taxes to be withheld, if any, Buyer shall comply with any applicable bilateral conventions against double taxation. If Buyer requires tax residence certificates from Seller to apply an exempted or reduced tax regime, Seller shall submit the appropriate certificates, upon Buyer’s written request. If Buyer, under the applicable Laws of any country other than Seller’s country of incorporation, deducts or withholds Seller Taxes, Buyer shall pay additional amounts to Seller so that Seller receives the full amount of the Contract Price, as though no such Seller Taxes had been deducted or withheld.

 

8.2

Exemptions

If either Party benefits from any tax, fee or Duty exemption (a “Benefitted Party”) applicable to the other Party or its Subcontractors (the “Other Party”), such Benefitted Party agrees to provide the Other Party, without charge, before invoicing, or before any other relevant event, documentation acceptable to supporting the tax or customs authorities supporting the exemption, together with instructions for the Other Party on the procedure for the exemption. Pursuant to state Law, certain tax and incentive programs are available to qualifying manufacturers in certain circumstances, including the Louisiana Quality Jobs Program, Enterprise Zone Program, and the Manufacturing Machinery and Equipment sales tax exclusion (collectively, the “Rebatable Louisiana Sales and Use Tax”). Owner has not determined which, if any, of these programs it will pursue. Seller shall cooperate with and assist Buyer and Owner and any designated tax and incentive consultant, and shall require Subcontractors to cooperate with and assist Buyer and Owner and any designated tax and incentive consultant, in obtaining tax and incentive benefits under these and any other available programs. Such assistance may include, but is not limited to, documenting purchase transactions, providing reports and supporting documents required to be submitted to obtain the tax and incentive benefits, and acting as agent for Owner in connection with the purchase of manufacturing machinery and equipment. If the determination of the proper amount of such Rebatable Louisiana Sales and Use Tax assessed on the Seller work is dependent upon knowing the actual cost incurred by Seller or its Subcontractors for the compensation of such Seller work, that portion of the audit devoted to reviewing the actual cost incurred by Seller or its Subcontractors for such Seller work shall be performed by Buyer or Owner’s tax consultant, which shall be retained by

 

A-32


Buyer or Owner at Owner’s sole expense. The Parties agree that (unless the amount of Rebatable Louisiana Sales and Use Tax properly payable for the Seller work is subject to audit, litigation, arbitration, subpoena or summons issued by a Governmental Authority) such tax consultant shall not disclose to Buyer or Owner the actual cost incurred by Seller or its Subcontractors for such work, but the Parties agree that such tax consultant may report to Buyer or Owner the proper Rebatable Louisiana Sales and Use Taxes properly payable under Applicable Law. No access to documents shall be granted to Buyer or Owner’s tax consultant until such tax consultant has signed a confidentiality agreement with Seller and any applicable Subcontractor with terms customary in the audit industry for audits of this kind.

 

8.3

No Taxes Included

The Contract Price does not include any Buyer Taxes. Therefore if any Buyer Taxes are required to be collected by Seller, such Buyer Taxes will be added to the Contract Price. For Country sales and use tax, and in other jurisdictions where applicable, Buyer may report or remit sales taxes or similar taxes directly if Buyer timely provides a direct pay or exemption certificate to Seller.

 

8.4

Exemptions for Steel and Aluminum Imports

Seller shall provide all reasonably requested support and assistance to Owner and Buyer related to such filings (including any joint filings by Owner and Seller or its Affiliates) or deliverables that are necessary or appropriate to request an exclusion or exemption from the remedies instituted in Presidential Proclamations Adjusting Imports of Steel Into the United States and Adjusting Imports of Aluminum Into the United States under Section 232 of the Trade Expansion Act of 1962 or similar tariff measures; although Seller does not guarantee that it will achieve any particular results related to Seller’s support so provided. Such assistance may include, but is not limited to, documenting purchase transactions and providing reports and supporting documents required to be submitted to obtain the exclusion or exemption. If and to the extent the same would (to Seller’s knowledge) reasonably be expected to result in Buyer becoming liable hereunder for the payment of additional amounts in relation to tariffs or Duties, Seller shall consult with Buyer in good faith in relation to the selection of an alternative Approved Subcontractor not located in Asia.

 

9.

DELIVERY, TITLE TRANSFER, RISK OF LOSS, STORAGE

 

9.1

Delivery

Seller shall deliver equipment for each Liquefaction Train DDP the marine offloading facility(ies) adjacent to the Site as designated by Buyer to Seller for the items to be delivered by ocean vessel/barge (Incoterms 2010) and DDP the Site for the items to be delivered by truck (Incoterms 2010) (collectively, the “Delivery Point”). Except for those obligations expressly set forth in the applicable Incoterms 2010 or as specifically provided under the Agreement, Seller shall not be liable in any claim asserted by Buyer with respect

 

A-33


to delivery of the Liquefaction Trains beyond the Delivery Point. The date of delivery for each Liquefaction Train is the date on which the Liquefaction Train in its entirety is delivered in accordance with this Clause 9.1 per the Incoterms to the Delivery Point. For the avoidance of doubt, delivery of an individual Liquefaction Train for purposes of the Agreement shall occur only when Seller has complied with all of its delivery obligations hereunder for that individual Liquefaction Train in its entirety. Except as otherwise provided in the Project Schedule or authorized in writing by Buyer, Seller shall not (a) deliver Liquefaction Trains 1 – 4 and 9 – 12 (as provided in the Project Schedule) to the Delivery Point more than [***] prior to the last day on which Buyer would be entitled to payment of a bonus pursuant to Clause 6.7, (b) deliver Liquefaction Trains 5 – 8 (as provided in the Project Schedule) to the Delivery Point more than [***] prior to the last day on which Buyer would be entitled to payment of a bonus pursuant to Clause 6.7, (c) deliver Liquefaction Trains 13 – 18 (as provided in the Project Schedule) to the Delivery Point more than [***] prior to the last day on which Buyer would be entitled to payment of a bonus pursuant to Clause 6.7, and (d) deliver Liquefaction Trains 19 – 24 (as provided in the Project Schedule) to the Delivery Point more than [***] prior to the last day on which Buyer would be entitled to payment of a bonus pursuant to Clause 6.7. Upon delivery Buyer shall unload delivered items within a reasonable time, and for all ocean vessel/barge shipments no later than [***] from delivery.

 

9.2

Seller Replacement of Non-Conforming Items

If after delivery to the Delivery Point, Buyer discovers any item of a Liquefaction Train that has been damaged prior to delivery or that fails to conform with the requirements of the Agreement, then after receiving written notification of such non-conformance, the Seller shall promptly repair or replace such item or items, at Seller’s sole cost and expense in accordance with Clause 17.

 

9.3

Title; Risk of Loss

Title to each item of the Liquefaction Train shall pass from the Seller to the Buyer as follows:

 

  (a)

for each such item shipped from within the United States, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9.4, upon the earlier of (i) when Seller makes such item available for shipment from the warehouse or from the manufacturer’s factory and (ii) payment by Buyer to Seller for such item;

 

  (b)

for each such item shipped from the European Union, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9.4, upon the earlier of (i) when such item has been cleared for export, or (ii) when such item departs from the territorial land, sea and overlying airspace of the country from which such item is shipped; and

 

A-34


  (c)

for each such item shipped from within any other country, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9.4, when such item departs from the territorial land, sea and overlying airspace of the country from which such item is shipped.

Seller shall maintain the risk of loss of each Liquefaction Train until such Liquefaction Train is delivered to the Delivery Point. Buyer shall only be responsible for risk of loss of each Liquefaction Train once such Liquefaction Train has been properly delivered to the Delivery Point.

 

9.4

Storage Locations

If any Liquefaction Train cannot be delivered to Buyer in accordance with the delivery terms herein due to Buyer’s request or any cause attributable to Buyer or its Affiliates and its or their officers, servants, agents, employees, sub-contractors, suppliers, and/or assigns, including transportation, staging, storage, or shipping service providers, upon notice to Buyer, Seller may ship such Liquefaction Train to a storage location mutually agreed to by Buyer and Seller; provided that Seller is not obligated to store or maintain any Liquefaction Train at Seller’s site past the Delivery Date for such Liquefaction Train. If such Liquefaction Trains are placed in a storage location pursuant to the preceding sentence of this Clause 9.4, the following conditions shall apply: (a) any amount of the Contract Price otherwise payable to Seller upon delivery to the Delivery Point shall be invoiced by Seller and payable by Buyer within thirty (30) Days of receipt by Buyer of such invoice and related documentation, including certification by Seller as to cause for storage; (b) all reasonable and documented incremental expenses incurred by Seller, such as for preparation for and placement into storage, handling, inspection, preservation, insurance, storage, removal charges and any taxes shall be reimbursed by Buyer upon submission of Seller’s invoices and related documentation, including evidence of such incremental expenses; and (c) upon receipt of notice from Buyer and payment of all undisputed amounts due under this Clause 9, Seller shall resume delivery of the Liquefaction Trains to the originally agreed Delivery Point (and any transportation costs or Duties incurred in the transportation of the Liquefaction Trains from storage to the Delivery Point shall not be subject to the limitation on Transportation Costs set forth in Clause 7.1). In the event the storage period extends for longer than [***], the Parties shall reconvene to agree on the schedule to reach delivery. To the extent shipment to storage of any of the Liquefaction Trains causes a delay in Seller’s schedule for delivery of the remaining Liquefaction Trains to be delivered hereunder, then Seller shall have the right to request a Change Order for adjustment of the Delivery Date for such remaining Liquefaction Trains.

 

10.

SELLER’S OBLIGATIONS

 

10.1

Compliance with Law

Seller shall, in performing its obligations under the Agreement, comply in all respects with all applicable professional standards, permits and Laws, rules, codes and regulations and the Liquefaction Train System shall be in full compliance with all applicable professional

 

A-35


standards, permits and Laws, rules, codes and regulations. Seller shall perform its obligations hereunder in accordance with the Project Schedule. Seller shall only use qualified personnel to perform its obligations hereunder. Seller shall be responsible for obtaining all licenses, permits and approvals from all Governmental Authorities that are required for Seller to perform its obligations under the Agreement.

 

11.

BUYER’S OBLIGATIONS

 

11.1

Access to and Possession of the Site

Access to the Site, including the use of Owner’s rights of way and easements, shall be granted to Seller by Buyer, only to the extent necessary and for the sole purpose of Seller performing its obligations under the Agreement.

 

11.2

Access not exclusive

The access to the Site provided by Buyer shall not be exclusive to Seller.

 

11.3

Personnel for Acceptance Tests

When each Liquefaction Train or Liquefaction Train System is ready for any acceptance or testing that is required under Appendix C (Scope of Supply & Project Schedule), Owner and/or Buyer shall provide the normal operating and maintenance personnel under the technical direction and supervision of Seller pursuant to the Services Agreement for such testing. For the avoidance of doubt, Seller’s personnel shall never be deemed to be Buyer’s or Owner’s employees, and vice versa.

 

11.4

Electricity, Water and Gas

Buyer shall be responsible at its own costs for the provision of all utilities, including but not limited to electricity, natural gas and water (including drinking water) for activities necessary to be performed on Site. Buyer shall also be responsible for and bear the costs of all arrangements for connection, metering and distribution.

 

11.5.

Organization on Site

Seller shall cause its personnel and its Subcontractor’s personnel to observe and comply with all safety and security protocols of Buyer when such personnel are on the Site, provided that Seller has been made aware of such safety and security protocols requirements.

 

A-36


12.

DOCUMENTATION BY SELLER

 

12.1

Reports

Seller shall prepare and submit to Buyer at the appropriate time the progress reports as detailed in Appendix C (Scope of Supply & Project Schedule). Seller shall submit all such other information and reports in relation to the Liquefaction Train System as Buyer shall reasonably request from time to time.

 

12.2

Submission of Technical Documentation

Appendix C (Scope of Supply & Project Schedule) specifies which Technical Documentation is to be submitted to Buyer by Seller. Seller shall submit such Technical Documentation to Buyer within the time required in Appendix C (Scope of Supply & Project Schedule). The Technical Documentation is required to be provided by Seller to Buyer. Buyer may give comments on any Technical Documentation submitted within [***] of Buyer’s receipt thereof, unless otherwise mutually agreed by Buyer and Seller, and Seller shall make the appropriate revisions to such Technical Documentation. The Technical Documentation shall include Seller’s standard Operation and Maintenance Manuals and the functional descriptions, in sufficient detail, to enable competent personnel to operate, maintain and repair the Liquefaction Train System.

 

12.3

Errors in Technical Documentation

Seller shall be liable for any Costs incurred in correcting any discrepancies, errors or omissions in the Technical Documentation prepared by it or its Subcontractors or on their behalf.

 

13.

MACHINERY, EQUIPMENT, SPARE PARTS AND WORKMANSHIP

 

13.1

Manner of Execution

The Liquefaction Train System shall be manufactured in the manner set out herein, including Clause 5, and in Appendix C (Scope of Supply & Project Schedule).

 

13.2

Quality of Materials

The Liquefaction Train System shall be brand new and unused, and all parts and components thereof shall be brand new and unused, upon delivery and shall in any event be in accordance with the standards and other requirements set forth in the Agreement.

 

13.3

Spare Parts

Not later than [***] prior to the Delivery Date of the first Liquefaction Train under the Agreement, Seller shall deliver to Buyer a detailed list and pricing proposal for all Subcontractor and Seller-recommended spare parts for operating and maintaining the Liquefaction Train System (including components and systems of each such Liquefaction Train System) (“Spare Parts”). Within [***] thereafter, Buyer shall specify in writing (via a Change Order) which items on the list of Spare Parts it wishes to purchase and the time (in accordance with Seller’s proposal) when such items should be delivered to a location designated by Buyer. The amount due from Buyer to Seller in connection with Spare Parts shall be based on current market prices.

 

A-37


14.

TESTING AND RIGHT TO INSPECT DURING MANUFACTURING

 

14.1

Documents

Seller documents that are included as Deliverables in Appendix C (Scope of Supply & Project Schedule) and annotated with an “A”, including Technical Documentation, shall be submitted to Buyer for approval, in accordance with the Project Schedule. Such documents shall be submitted to Buyer in substantially complete packages for each Liquefaction Train to be delivered hereunder.

 

14.2

Inspection and testing during manufacturing

Each Buyer Inspection Party shall be entitled during the manufacturing of the Liquefaction Train System to inspect and examine the materials and workmanship in accordance with the inspection test plan to be mutually agreed upon in accordance with Appendix C (Scope of Supply & Project Schedule), to attend any scheduled test of the Liquefaction Train System (or major components thereof) on Seller’s premises during working hours, and to check the progress of manufacture of the Liquefaction Train System (or major items thereof) to be supplied under the Agreement during normal business hours. If components of the Liquefaction Train System are being manufactured on other premises, Seller shall, upon receipt of written request from Buyer or Owner, make commercially reasonable efforts to obtain for the Buyer Inspection Parties permission to inspect, examine and attend any test, provided that such inspection, examination or attendance of tests shall not delay the execution of the works (without prejudice to Clause 14.3). Such inspection, examination or attendance of tests, if made, shall not grant access to areas of Seller’s facilities not related to the execution of Seller’s obligations under Appendix C (Scope of Supply & Project Schedule) or where other work of a proprietary nature is being performed.

 

14.3

Dates for inspection and testing

 

  (a)

Each Buyer Inspection Party shall have the right to witness such activity of inspection or testing required in accordance with Appendix C (Scope of Supply & Project Schedule). Buyer and Owner each shall have the right to ask for additional witness points during the manufacturing of the Liquefaction Trains, subject to Seller’s right to request a Change Order for any adverse impact on the delivery of the Liquefaction Trains as a result of such additional witness points.

 

  (b)

The Parties shall agree (at least thirty (30) Days prior to the proposed date) on the date on, and the place at, which the Liquefaction Train System and/or portion(s)/module(s) will be ready for inspection and/or testing. Should any postponement become necessary, Seller shall provide written notification of the same at least three (3) Working Days prior to the originally scheduled date. Each of Buyer and Owner shall give Seller two (2) Working Days’ notice in writing of its intention to attend the tests, or ask for a postponement of not more than twenty-four (24) hours if required.

 

A-38


  (c)

Should Buyer or Owner not attend the tests at the place and on the date which Seller has stated in its notice, Seller may proceed with the tests and shall forthwith forward to Buyer and/or Owner the test results.

 

  (d)

If Buyer or Owner decides, at receipt of the test results, that the test should be repeated in its presence (even though the test results, in the opinion of Seller, were satisfactory), all the consequences of such repeat test (additional Cost and delay suffered by Seller) shall be borne by Buyer, unless such repeat tests give results materially not in accordance with the Agreement, in which case they shall be borne by Seller. If, however, neither Buyer or Owner notifies Seller, within five (5) Working Days after receipt of the test results, that it has decided that the test should be repeated in its presence, Seller shall not be obliged to repeat such test.

 

  (e)

Seller shall provide at least ten (10) Days’ advance notification to Buyer or a third party, acting on Buyer’s behalf, of any inspection or test in accordance with the procedures set forth in Appendix E (Quality Assurance and Quality Control). Buyer and Owner shall have the right to add by written notice to Seller witness points and/or holding points, either for Buyer or Owner or any such third party.

 

14.4

General right to inspect during manufacturing

Each Buyer Inspection Party shall be entitled to inspect the Liquefaction Train System during Seller’s manufacturing at Seller’s facilities, during working hours after having given to Seller a reasonable notice. Any inspection of the Liquefaction Train System by any Buyer Inspection Party shall not release Seller from any obligation under the Agreement nor constitute an acceptance by Buyer or any other party of any portion of the Liquefaction Train System inspected or tested.

 

14.5

Certificate of testing

As and when the Liquefaction Train System shall have passed the factory acceptance testing referred to in Clause 1.6 of Appendix C (Scope of Supply & Project Schedule) during the manufacturing (the “Factory Acceptance Tests”), Seller shall, within thirty (30) days following completion of any Factory Acceptance Test, whether such Factory Acceptance Test passed or failed, provide the factory report with all required supporting data (including any anomalies encountered during the Factory Acceptance Test), signed by Seller and the factory performing such Factory Acceptance Tests and deliver the same to Buyer. All reports and related documentation associated with the Factory Acceptance Tests shall be stored in the manufacturing data books prepared in accordance with Seller’s standard practice, and all such manufacturing data books will be finally delivered to Buyer in electronic form no later than ninety (90) days after the final Delivery Date.

 

A-39


14.6

Failure on tests or inspection

If as a result of any inspection, examination or test of the Liquefaction Train System, Buyer or Owner, as the case may be, shall consider with reasonable justification that the Liquefaction Train System and/or portion(s)/module(s) contain any Defect or is not in accordance with the Agreement, Buyer or Owner, as the case may be, shall notify Seller accordingly stating in writing its objection and reasons therefore. Seller shall promptly investigate Buyer’s or Owner’s claim, and if a Defect is found to exist, Seller shall rework and reperform its obligations under Appendix C (Scope of Supply & Project Schedule) necessary to remedy the Defect and bring the results of Seller’s performance of its obligations under Appendix C (Scope of Supply & Project Schedule) back in conformance with the requirements of the Agreement. Thereafter, if a Defect in any component of a Liquefaction Train is discovered before the delivery of such Liquefaction Train to the Delivery Point, if requested by Buyer or Owner, as the case may be, the necessary tests not passed shall be repeated under the same terms and conditions, provided that all Costs resulting from the repetition of the tests shall be for Seller’s account.

 

14.7

Right to inspect by others

In exercising its rights to inspect the Liquefaction Train System and/or to attend any tests under the Agreement, each of Buyer and Owner shall, upon consent of Seller and at Buyer’s cost, be entitled to be accompanied by any Lenders, Lender’s Engineer, advisor(s) of Buyer, or any adjusters or insurers’ representatives, provided that such accompanying Persons may be first required by Seller to enter a separate non-disclosure agreement with Seller. Seller shall allow all such Persons the same rights of inspection and test attendance as are enjoyed by Buyer or Owner pursuant to the Agreement, whether or not such inspection or attendance is made with Buyer or Owner, provided that such Persons may be first required by Seller to enter a separate non-disclosure agreement with Seller.

 

15.

DELIVERY OF THE LIQUEFACTION TRAINS

 

15.1

Delivery

Unless Buyer shall otherwise direct, no Liquefaction Train shall be delivered except in accordance with the schedule of Delivery Dates in the Project Schedule.

 

15.2

Packing and Marking

The Liquefaction Train System and/or portion(s)/module(s) shall be packed in boxes/containers or packing/packaging in accordance with Seller’s standards set forth in Appendix C (Scope of Supply & Project Schedule).

 

15.3

Detailed specification and procedure

On or before ten (10) Days prior to the Delivery Date of a component of a Liquefaction Train, Seller shall prepare and submit to Buyer, for information and approval, the detailed specification of packing and marking, specify the type and number of documents to be prepared and transmitted, with the form for each of them, all in accordance with the Agreement. Not less than ninety (90) Days prior to the first Delivery Date, the Parties shall meet and discuss the shipping procedures, including marking, cargo list preservation, preservation requirements and other related matters.

 

A-40


15.4

Warranty of ownership

Seller warrants and guarantees title to the Liquefaction Train System provided under the Agreement, and Seller warrants and guarantees that title and ownership thereto shall pass to and vest in Buyer, as agreed in the Agreement, free and clear of any and all Liens.

 

16.

COMPLIANCE WITH LAWS, CODES AND STANDARDS

 

16.1

Contract Price Basis

The Contract Price is based on Seller’s design, manufacture, testing and delivery of the Liquefaction Train System pursuant to:

 

  (a)

Seller’s design criteria, manufacturing processes and procedures and quality assurance program;

 

  (b)

those industry specifications, codes and standards that are (i) identified in Appendix C (Scope of Supply & Project Schedule) or (ii) otherwise applicable to the Liquefaction Train System or Seller’s obligations under the Agreement;

 

  (c)

those Laws in effect as of the Effective Date, which are applicable to the Liquefaction Train System or Seller’s obligations under the Agreement; and

 

  (d)

the specifications and other requirements contained in the Agreement, including Appendix C (Scope of Supply & Project Schedule).

 

16.2

Export Controls

The Parties agree to comply with all applicable export control and economic sanctions Laws in the performance of the Agreement, including any restrictions or conditions regarding the export, re-export, or other transfer of the Deliverables under the Agreement that are in effect now or are hereafter imposed by the any Governmental Authority. Each Party shall be responsible for its own compliance with applicable export control and economic sanctions Laws with regards to their Affiliates, employees, facilities and activities. These restrictions and conditions include, but are not limited to, (a) restrictions and export licensing requirements governing the export, re-export, or other transfer to other persons, entities, or countries of the Deliverables under the Agreement, (b) restrictions and export licensing requirements governing the export or other transfer of foreign-developed information that incorporates the Deliverables under the Agreement, (c) any applicable restrictions on the export, re-export, or other transfer of the Deliverables under the Agreement to countries and Persons that are subject to applicable sanctions, embargoes, or other prohibitions, and (d) any applicable restrictions on the export or other transfer of the

 

A-41


direct product of technical data. Each Party shall notify the other Party in writing prior to transferring any commodity, software or technology that is: (i) controlled at a level greater than EAR99 or Anti-Terrorism controls under the Export Administration Regulations (“EAR”); or (ii) subject to the jurisdiction of an export control regime other than the EAR. Seller acknowledges that, in connection with the performance of the Agreement, the export and customs Laws and regulations of the Country apply to the furnishing and shipment of the Liquefaction Train System.

 

16.3

Nuclear Activity Restrictions

The Liquefaction Train System sold hereunder is not intended for application (and shall not be used) in connection with any nuclear installation or activity and Buyer warrants that it shall not use the Liquefaction Train System for such purposes, or permit others to use or permit others to use the Liquefaction Train System for any such purposes. If, in breach of the foregoing, any such use of the Liquefaction Train System sold hereunder occurs, Seller shall have no liability for any nuclear or other damage, injury or contamination, and Buyer shall indemnify Seller, its Affiliates and suppliers of every type and tier against any such liability, whether arising as a result of breach of contract, warranty, indemnity, tort (including negligence), strict liability or otherwise.

 

16.4

Required Authorizations

Notwithstanding any other provisions herein, Seller shall be responsible for timely obtaining of any required authorization, such as an import license, foreign exchange permit, work permit or any other authorization from a Governmental Authority that are required for Seller to perform its obligations under the Agreement.

 

16.5

Anti – Corruption

 

  (a)

Each Party represents, warrants and covenants to the other Party that neither the representing Party, nor any of its Affiliates (or any of their respective principals, partners or funding sources), is currently (i) a Person designated by the U.S. Department of Treasury’s Office of Foreign Assets Control as a “specially designated national or blocked person” (“SDN”) or similar status, (ii) a person otherwise identified by a government or legal authority as a person with whom the other Party is prohibited from transacting business; (iii) directly or indirectly owned or controlled by an SDN or the government of any country that is subject to an embargo by the government of the Country; or (iv) a Person acting on behalf of an SDN or a government of any country that is subject to an embargo by the government of the Country. Each Party agrees that it will notify the other Party in writing immediately upon the occurrence of any event that subsequently results in any of the designations set forth in this Clause 16.5(a).

 

A-42


  (b)

Each Party shall, in the performance of the Agreement, comply with all Laws, orders, directives, and regulations in effect on February 26, 2021 and the Effective Date and as they may have been or be amended from time to time that are applicable to such Party. Notwithstanding anything contained herein to the contrary, the Agreement shall not be interpreted or applied so as to require either Party to do, or to refrain from doing, anything that would constitute a violation of federal or state laws and regulations applicable to it, including the Foreign Corrupt Practices Act of 1977, 15 U.S.C. § 78dd-2, the OECD Anti-Bribery Convention, the U.K. Bribery Act of 2010, E.U. and E.U. member country anti-bribery and corruption laws, laws or regulations restricting participation in or compliance with certain foreign boycotts, directly or indirectly, as contained in the U.S. Export Administration Act of 1979, the U.S. Internal Revenue Code or any similar statute, regulation, order or convention binding on such Party, as each may be amended from time to time, and including implementing regulations promulgated pursuant thereto (collectively, the “Anti-Corruption Laws”). Without limiting the foregoing, each Party agrees on behalf of itself, its Affiliates and their respective directors, officers, employees, agents and contractors, not to pay any fees, commissions or rebates to any employee, officer or agent of the other Party or its Affiliates or their respective shareholders, or provide or cause to be provided to any of them any gifts or entertainment of significant cost or value in connection with the Agreement or in order to influence or induce any actions or inactions in connection with the commercial activities of the Parties in connection with the Agreement.

 

  (c)

Each Party represents, warrants and covenants with respect to itself and its Affiliates that (i) it and its Affiliates are being and have been operated in compliance in all material respects with the Anti-Corruption Laws, (ii) neither it nor any of its Affiliates has received any written notice or claim alleging any material violation under any of the Anti-Corruption Laws, and (iii) neither it nor any of its Affiliates, nor any of their respective directors, officers, or employees (or, to the best of the representing Party’s knowledge and belief, any partner, intermediary or other Person acting or purporting to act on behalf of such Party or any of its Affiliates) has knowingly directly or indirectly paid, offered, given, promised to pay or authorized the payment of any money or anything of value to (A) any candidate for public office, any past or present employee, director, officer, official, representative or agent of any government, government or legal authority, instrumentality, or any public international organization (“Government Official”), (B) any Person acting for or on behalf of any Government Official, or (C) any other Person at the suggestion, request, direction or for the benefit of any of the above-described Persons to obtain, retain or direct business or to obtain special concessions or pay for favorable treatment for business secured or for special concessions already obtained.

 

  (d)

Neither Seller, nor any of its Affiliates, directors, officers, employees or agents, shall use its relationship with Buyer to attempt to disguise the sources of illegally-obtained funds. Seller further represents and warrants that no such attempt of the sort described in this Clause 16.5(d) has been made prior to the Effective Date.

 

  (e)

Each Party shall keep all records necessary to confirm compliance with this Clause 16.5 for a period of five (5) years following the year for which such records apply.

 

A-43


If a Party asserts that the other Party is not in compliance with this Clause 16.5, the asserting Party shall notify the other Party indicating the type of non-compliance asserted. After such notification, the asserting Party may cause an independent auditor to audit the records of the other Party in respect of the asserted non-compliance. The costs of any independent auditor under this Clause 16.5(e) shall be paid (i) by the audited Party, if such Party is determined not to be in compliance with this Clause 16.5 or (ii) by the asserting Party, if the other Party is determined to be in compliance with this Clause 16.5.

 

  (f)

Seller agrees to indemnify, defend, release and hold Buyer, Buyer’s Parties and its and their shareholders, directors, officers, employees, agents, consultants or representatives harmless from any penalties and fines assessed by government authorities arising out Seller’s breach of any or all of this Clause 16.5. Buyer agrees to indemnify, defend, release and hold Seller Parties harmless from any penalties and fines assessed by government authorities arising out Buyer’s breach of any or all of this Clause 16.5. Any breach of any of the representations, warranties and covenants in this Clause 16.5 shall be grounds for termination of the Agreement, and if Seller is the breaching Party, there shall be no further payments due to Seller upon termination.

 

17.

WARRANTY

 

17.1

Warranty; Warranty Period

 

  (a)

Seller warrants to Buyer that (i) each Liquefaction Train shall be (A) free from defects in material, workmanship and title and (B) designed, engineered and manufactured in accordance with applicable Laws, the specifications referenced in the Agreement and the other requirements of the Agreement, and (ii) the performance by Seller of its obligations under Appendix C (Scope of Supply & Project Schedule) shall be free from defects and performed in accordance with applicable Laws and the other requirements of the Agreement. Except as set forth in Clause 17.2, the “Warranty Period” for the warranties in this Clause 17.1 shall be the period starting on the date of Substantial Completion of the Liquefaction Train for the first Liquefaction Train and ending upon: (i) in respect of the first [***] Liquefaction Trains set forth in the Project Schedule, the earlier of (1) [***] after the date of Substantial Completion of the Liquefaction Train System, and (2) [***] from the date that Seller delivered the applicable Liquefaction Train to the Delivery Point, and (ii) in respect of the last [***] Liquefaction Trains set forth in the Project Schedule, the earlier of (1) [***] after the date of Substantial Completion of the Liquefaction Train System and (2) [***] from the date that Seller delivered the applicable Liquefaction Train to the Delivery Point, provided that Buyer and Seller shall enter into the Preservation Agreement, for any Liquefaction Trains that are shipped to storage, if the storage period is for a period greater than [***] .

 

A-44


  (b)

Buyer may, from time to time during the Warranty Period, issue a Change Order (and Seller shall execute such Change Order) extending the Warranty Period for one (1) or more Liquefaction Trains for the number of months specified in such Change Order such total extension not to exceed [***] . Such Change Order shall increase the Contract Price by an amount equal to [***] per month for each Month that the Warranty Period for [***] Liquefaction Trains is extended by Buyer pursuant to the preceding sentence.

 

17.2

Remedial Actions

 

  (a)

If a failure to meet any of the warranties set forth in Clause 17.1 appears within the Warranty Period, Buyer shall promptly notify Seller in writing and make the defective component available for correction/inspection within a commercially reasonably time period thereafter. Seller, at its expense, shall thereafter correct any Defect by: (i) re-performing the defective performance of its obligations under Appendix C (Scope of Supply & Project Schedule); and (ii) repairing or replacing the defective Liquefaction Train System(s) or components thereof. Seller shall not be responsible for material removal or replacement of systems, structures or other parts of the Facility to grant Seller access to the Liquefaction Train System. Any repair, replacement or re-performance by Seller hereunder shall extend the applicable Warranty Period on such repaired, replaced or re-performed component of the Liquefaction Train System for a period of [***] , provided that in no event shall the Warranty Period extend beyond [***] from the date of Substantial Completion of the Liquefaction Train System. Such warranty extension is in lieu of and not in addition to the extension of the Warranty Period for Serial Defects contemplated in Clause 17.2(c).

 

  (b)

Seller shall not be liable for Defects that arise after the Warranty Period, as extended hereunder, has expired. The testing of any replaced or repaired parts of the Liquefaction Train System, equipment or components shall be performed in the same manner as originally contemplated under the Agreement, and Buyer shall be notified of and may be represented at all tests that may be made. Seller shall not be responsible for the removal or replacement of any systems, structures or other parts of Buyer’s facility, which were not provided by Seller, in order for Seller to gain access to the Liquefaction Train System.

 

  (c)

If, prior to the expiration of the Warranty Period, [***] of the same component of the Liquefaction Train System experience a Defect of an identical or nearly identical nature that causes or could reasonably be expected to cause an outage of a Liquefaction Train (herein, a “Serial Defect”), then Seller shall examine the cause of the Serial Defect and (i) undertake technical analysis of the underlying problem in order to determine (A) the root cause of such Serial Defect and (B) the repairs or replacements that may be required to avoid future occurrences of such Serial Defect, (ii) prepare and provide to Buyer and Owner a written report setting forth the results of such analysis, (iii) promptly redesign if necessary and repair or

 

 

A-45


replace any Liquefaction Train, as necessary, and (iv) if such Serial Defect root cause requires redesign, repair or replacement of the defective component or Liquefaction Train, extend the Warranty Period for such redesigned, repaired or replaced component for an additional period of [***] , all at no additional cost to Buyer or Owner. Such warranty extension for Serial Defects is in lieu of and not in addition to the extension of the Warranty Period contemplated in Clause 17.2(a).

 

  (d)

If Seller fails to commence the corrective work for any Defects, Serial Defects or damage within a reasonable period of time not to exceed [***] after receiving notification by Buyer or Owner regarding such Defect, Serial Defect or damage, Buyer or Owner, at their sole discretion, may (in addition to any other remedies that each of them have under the Agreement) proceed to commence to correct such Defect, Serial Defect or damage at Seller’s risk and expense and the Costs incurred by Buyer or Owner, as the case may be, in performing such corrective work shall be paid by Seller.

 

17.3

Warranty Conditions

Seller does not warrant the Liquefaction Train System or any repaired or replaced parts against normal wear and tear or from the involvement in an accident. The warranties and remedies set forth herein are further conditioned upon:

 

  (a)

the proper storage (to the extent it is the responsibility of Buyer or its Affiliates and its or their officers, servants, agents, employees, sub-contractors, suppliers, and/or assigns, including transportation, staging or storage, or shipping service providers), installation, operation, and maintenance of the Liquefaction Train System in conformance with the operation instruction and installation manuals (including revisions thereto) provided by Seller; and

 

  (b)

repair or modification of the Liquefaction Train System pursuant to Seller’s instructions or approval.

Seller does not warrant any equipment or services of others designated by Buyer where such equipment or services are not normally supplied by Seller.

 

17.4

Warranties Exclusive

[***] THE PRECEDING PARAGRAPHS OF THIS CLAUSE 17 SET FORTH THE EXCLUSIVE REMEDIES FOR ALL CLAIMS BASED ON FAILURE OF OR DEFECT IN THE LIQUEFACTION TRAIN SYSTEM OR PERFORMANCE OF SELLER’S OBLIGATIONS UNDER APPENDIX C (SCOPE OF SUPPLY) PROVIDED UNDER THE AGREEMENT, WHETHER THE FAILURE OR DEFECT ARISES BEFORE OR DURING THE WARRANTY

 

A-46


PERIOD AND WHETHER A CLAIM, HOWEVER INSTITUTED, IS BASED ON CONTRACT, INDEMNITY, WARRANTY, TORT/EXTRA-CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY OR OTHERWISE. THE FOREGOING WARRANTIES ARE EXCLUSIVE AND ARE IN LIEU OF ALL OTHER WARRANTIES, CONDITIONS AND GUARANTEES WHETHER WRITTEN, ORAL, IMPLIED OR STATUTORY. NO IMPLIED STATUTORY WARRANTY OR MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE SHALL APPLY.

 

18.

INTELLECTUAL PROPERTY

 

18.1

Work Product

Any concept, idea, product, process, technique, discovery, improvement, know-how, work of authorship (including without limitation documents, specifications, calculations, maps, sketches, notes, reports, data, models, samples, drawings, designs, videos and electronic software) or other information, including the Technical Documentation, in each case whether subject to copyright registration or patent protection or not, other than Seller Developed Intellectual Property, that was first conceived, reduced to practice or created by Seller or any of its employees or Subcontractors in the performance of its obligations hereunder and (a) was furnished by Seller to Buyer as a Deliverable under the Agreement or (b) is an improvement to or otherwise incorporates Buyer’s Background Intellectual Property or Buyer’s Developed Intellectual Property (collectively, “Work Product”) shall be the sole property of Buyer. Seller agrees to assign and hereby assigns to Buyer all rights, title and interest throughout the world in and to all Work Product, including all Intellectual Property therein.

 

18.2

Background Intellectual Property

As between the Parties, each Party exclusively owns all right, title, interest in the Background Intellectual Property created or acquired by it. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty-free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses to the rights granted to Buyer under this Clause 18.2 and to freely transfer the rights granted to Buyer under this Clause 18.2 to third parties, other than to Seller’s Competitors) [***]. Seller expressly reserves all other rights in Seller Background Intellectual Property. Buyer hereby grants to Seller and Seller’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights [***].

 

A-47


18.3

Seller Developed Intellectual Property

As between Seller and Buyer, all improvements to the Background Intellectual Property of Seller that are first conceived, reduced to practice or created by Seller or any of its employees or Subcontractors in the performance of Seller’s obligations under the Agreement (the “Seller Developed Intellectual Property”) shall be owned by Seller, subject to Buyer’s rights in any Background Intellectual Property of Buyer contained therein. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses and to freely transfer the rights granted to Buyer under this Clause 18.3 to third parties other than the Seller Competitors) [***]. Seller expressly reserves all other rights in Seller Developed Intellectual Property.

 

18.4

Buyer Developed Intellectual Property

As between Seller and Buyer, all improvements to the Background Intellectual Property of Buyer that are first conceived, reduced to practice or created by Buyer or any of its employees, contractors or consultants in the performance of Buyer’s obligations under the Agreement (the “Buyer Developed Intellectual Property”) shall be owned by Buyer, subject to Seller’s rights in any Background Intellectual Property of Seller contained therein.

 

18.5

Instruments of Service

All reports, design drawings, specifications, field data and notes, calculations, estimates and other documents prepared in the performance of Seller’s obligations under the Agreement by Seller or any of its employees or Subcontractors as instruments of service, other than any such items that are Work Product and other than any items that include Buyer Developed Intellectual Property and/or Buyer’s Background Intellectual Property (collectively, the “Instruments of Service”), shall remain Seller’s property. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights [***].

 

A-48


18.6

Outside Intellectual Property

(a) Seller shall not use any trade secret, invention, work of authorship, software, patent or protectable design conceived or developed by a party other than Buyer or Seller (collectively, the “Outside Intellectual Property”) in connection with the Agreement unless Seller has secured the rights to use such Outside Intellectual Property for the benefit of Buyer. To the extent Seller uses such Outside Intellectual Property in connection with the Agreement and to the extent that Seller has the legal and contractual right to do so, Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses to the rights granted to Buyer under this Clause 18.6 and to freely transfer the rights granted to Buyer under this Clause 18.6 to third parties) [***].

(b) Upon Buyer’s request, Seller agrees to provide, without any additional charge, a copy of the Exchanger Design and Rating native file for the dynamic simulation of the Liquefaction Train (the “EDR File”) generated by the supplier of the Cold Boxes. Subject to Clause 22, Buyer shall have the right to use the EDR File for the sole purpose of (i) [***], and (ii) [***]. Except for the use rights set forth herein, nothing in this Agreement is deemed to grant or transfer any Intellectual Property Rights in the EDR File to Buyer. The EDR File shall not be considered a Deliverable and shall be provided by Seller “AS IS” without warranties of any kind.

 

18.7

Restrictions on Use

Except to the extent required by applicable Law, copies of any Work Product, Seller Developed Intellectual Property or Instruments of Service shall not be released to any other party by Seller, or to any Seller Competitors, or used by Seller for any purpose that is unrelated to the Facility, except in response to a subpoena, court order or other legal process, or to the extent that the foregoing materials were already within the public domain or in the possession of third parties, without the prior written approval of Buyer, which Buyer may withhold in its sole and absolute discretion and excepting that the Parties agree that the restrictions on use in this Clause 18 shall not preclude Seller from using, and Buyer specifically agrees, that Seller retains rights to use (including on subsequent projects or scopes of work with third parties) the Seller’s Know-How, Seller Developed Intellectual Property and Instruments of Service, but subject to the confidentiality obligations set forth in Clause 22. At the expiration or earlier termination of the Agreement, Seller shall promptly deliver to Buyer (but in any event, no later than thirty (30) Days from the date of such expiration or termination) all of the Work Product in all forms and formats including without limitation hard copies and electronic files on disks.

 

A-49


18.8

Notification and Indemnification

If either Party is made the subject of any Intellectual Property Claim, such Party shall promptly notify the other Party in writing. Buyer shall defend and indemnify Seller against those Intellectual Property Claims only to the extent that Seller’s allegedly infringing or misappropriating conduct is expressly requested in writing by Buyer. This indemnity shall not extend to any conduct of Seller which is discretionary to Seller. Seller shall defend, indemnify and hold the Buyer Parties harmless against any Losses arising from any Intellectual Property Claim. In no event shall Seller have such indemnity obligations for any Intellectual Property Claim arising from or in connection with any material modification by Buyer that was not authorized by Seller. Buyer shall (a) promptly notify Seller in writing of its receipt of such Intellectual Property Claim and (b) make no admission of liability and (c) not take any position materially adverse to Seller regarding such Intellectual Property Claim. Without limiting the foregoing, Seller shall, at its own expense and option, promptly, but in no event later than thirty (30) Days following the date of notice from Buyer (i) settle or defend the claim or any suit or proceeding and pay all damages and costs awarded in it against Buyer, (ii) procure for Buyer or reimburse Buyer for procuring, the right to continue using the deliverables from Seller’s performance of its obligations under the Agreement, including the infringing service, the Technical Documentation, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim, (iii) modify such infringing deliverables, including the Technical Documentation, service, materials, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim so that they become non-infringing or (iv) replace the infringing deliverables, including any Technical Documentation, service, materials, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim with non-infringing deliverables to the satisfaction of Buyer; provided that in no case shall Seller take any action which adversely affects Buyer’s continued use and enjoyment of the applicable service, materials, Work Product, or other Intellectual Property without the prior written consent of Buyer. Buyer’s acceptance of the materials, Deliverables, Work Product, and other equipment or any other component of Seller’s performance under the Agreement shall not be construed to relieve Seller of any obligation hereunder. The Buyer Parties agree to cooperate and assist Seller in the defense of any Intellectual Property Claims, at Seller’s cost. Any Buyer Party which seeks to settle any Intellectual Property Claim shall seek the prior approval of Seller, which approval shall not be unreasonably withheld, conditioned, or delayed, in respect of such settlement.

 

18.9

Seller Simulation Models

Upon Buyer’s request, Seller agrees to provide, if and when requested by Buyer, without any additional charge, one permit for permission based access to Seller’s web-based service that provides access to a copy of the Liquefaction Train transient simulation model created, conceived or developed by Seller or any of its employees or Subcontractors based on a Subcontractor proprietary software named [***] (the “BH-Transient Liquefaction Train Simulation Model”), and, subject to Clause 22, Seller hereby

 

A-50


grants to Buyer and Buyer’s Affiliates a, royalty free, non-transferable, non-sublicensable, worldwide, fully paid-up, non-exclusive license rights [***]. The BH-Transient Liquefaction Train Simulation Model shall not be considered a Deliverable and shall be provided by Seller “AS IS” without warranties of any kind.

 

18.10

Survival

The provisions of Clause 18 shall survive the completion or early termination of the Agreement.

 

19.

INDEMNITY AND LIMITATION OF LIABILITY

 

19.1

Indemnification

 

  (a)

Seller shall indemnify, defend, release and hold harmless the Buyer Parties from any physical damage to property of third parties or injury to Persons, including death, to the extent resulting directly from the negligence or willful misconduct of Seller or its officers, servants, agents, employees, and/or assigns while engaged in activities relating to the Agreement. Buyer shall indemnify, defend, release and hold harmless the Seller Parties from any physical damage to property of third parties or injury to Persons, including death, to the extent resulting directly from the negligence or willful misconduct of Buyer, its officers, servants, agents, employees, and or assigns, while engaged in activities relating to the Agreement. In the event such damage or injury is caused by the joint or concurrent negligence of Seller and Buyer, the loss shall be borne by each Party in proportion to its negligence.

 

  (b)

For the purposes of this Clause 19.1 no portion of the Facility or the Site shall be considered third party property and Buyer and Owner release claims related to property damage to the Facility or the Site caused by Seller (and including those property damage claims caused by Seller’s negligence or willful misconduct); provided, however, Seller shall, to the extent directly caused by the negligence or willful misconduct of Seller, be responsible to Buyer and Owner (subject to the limitations of Clause 19.2 and Clause 19.3) for: [***], Seller shall reimburse Buyer and Owner (without duplication) for the deductible amounts related to the damage to the Facility or the Site.

 

A-51


19.2

Limit of Liability

EXCEPT, WITH RESPECT TO [***], THE TOTAL LIABILITY OF EACH PARTY FOR ALL CLAIMS OF ANY KIND, WHETHER IN CONTRACT, WARRANTY, INDEMNITY, TORT/EXTRA-CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY, OR OTHERWISE, ARISING OUT OF OR RELATING TO THE PERFORMANCE OR BREACH OF THE AGREEMENT OR USE OF THE LIQUEFACTION TRAIN SYSTEM, SHALL NOT EXCEED [***]. BUYER’S PAYMENT OF THE CONTRACT PRICE SHALL NOT COUNT TOWARDS BUYER’S CONTRACT PRICE LIMIT OF LIABILITY HEREUNDER. FURTHER, WITH RESPECT TO SELLER’S FAILURE TO ACHIEVE (1) EACH OF THE LIQUEFACTION TRAIN PERFORMANCE GUARANTEES AND (2) EACH OF THE LIQUEFACTION TRAIN SYSTEM PERFORMANCE GUARANTEES, BUYER AGREES, AFTER ANY TERMINATION OF THE AGREEMENT BY BUYER, NOT TO ASSERT ANY CLAIMS AGAINST SELLER FOR MONETARY DAMAGES IN EXCESS OF [***] [***]. FOR THE AVOIDANCE OF DOUBT, SELLER’S OBLIGATIONS UNDER A CLAIM FOR SPECIFIC PERFORMANCE ARE NOT LIMITED BY THIS CLAUSE 19.2.

 

19.3

Waiver of Consequential Damages

IN NO EVENT, WHETHER AS A RESULT OF BREACH OF CONTRACT, WARRANTY, INDEMNITY, TORT/EXTRA CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY, OR OTHERWISE, SHALL EITHER PARTY OR ITS SUBCONTRACTORS OR SUPPLIERS BE LIABLE FOR LOSS OF PROFIT OR REVENUES, LOSS OF USE OF THE LIQUEFACTION TRAIN SYSTEM OR ANY ASSOCIATED EQUIPMENT, DOWNTIME COSTS, CLAIMS OF

 

A-52


A PARTY’S CUSTOMERS FOR SUCH DAMAGES, OR FOR ANY SPECIAL, CONSEQUENTIAL, INCIDENTAL, INDIRECT OR EXEMPLARY DAMAGES. THE WAIVERS SET FORTH IN THIS CLAUSE 19.3 SHALL NOT APPLY TO LIQUIDATED DAMAGES OR ANY THIRD PARTY INDEMNIFICATION CLAIMS UNDER THE AGREEMENT, PROVIDED THAT EACH OF THE SELLER EXCLUDED PARTIES AND BUYER EXCLUDED PARTIES SHALL NOT BE DEEMED A THIRD PARTY FOR THE PURPOSES OF THIS CLAUSE 19.3.

 

19.4

Seller Protection from Third Parties

If Buyer is furnishing Seller’s Liquefaction Train System to a third party by contract or using Seller’s Liquefaction Train System at a facility owned by a third party, Buyer shall [***].

 

20.

DISPUTE RESOLUTION

 

20.1

Disputes

Any dispute, controversy or claim between the Parties that arises out of, under or in connection with the Agreement, including its interpretation, performance, enforcement, termination, validity or breach (each a “Dispute”) shall be subject to resolution under this Clause 20, which shall be the exclusive dispute resolution method for any such Dispute. A Party wishing to declare a Dispute shall deliver to the other Party a notice identifying the disputed issue (a “Notice of Dispute”). Following the delivery of a Notice of Dispute, the Parties shall attempt in good faith to resolve such Dispute promptly through negotiation. If the Dispute has not been resolved within thirty (30) Days after the date on which the Notice of Dispute was delivered, then any Party shall be permitted to submit such Dispute to binding arbitration in accordance with Clause 20.2.

 

20.2

Arbitration

Any Dispute that is not resolved pursuant to Clause 20.1 shall be exclusively and definitively resolved through final and binding arbitration conducted in accordance with the Rules of Arbitration of the International Chamber of Commerce (the “ICC Rules”), which (except as modified by this Clause 20.2) are deemed to be incorporated by reference into this Clause 20.2.

 

  (a)

The arbitration tribunal shall consist of three (3) arbitrators. One (1) arbitrator shall be appointed by Buyer, one (1) arbitrator shall be appointed by Seller, and the third arbitrator shall be selected by agreement of the first two (2) arbitrators. If either of the first two (2) appointments is not made within thirty (30) Days after the request

 

A-53


  for arbitration, or if the first two (2) arbitrators fail to agree on a third arbitrator within thirty (30) Days after the later of them has been appointed, the unfilled appointment will be made, at the request of either Party, by the ICC. No arbitrator appointed pursuant to this Clause 20.2(a) shall be an employee, agent, contractor, competitor or former employee, agent or contractor of, or have or have had any material interest (directly or indirectly) in the business of or in any Party or any of its Affiliates. Each arbitrator shall be knowledgeable with respect to engineering, procurement and construction contracts and shall be fluent in the English language.

 

  (b)

Unless the Parties agree in writing otherwise:

 

  (i)

the seat of arbitration shall be New York, New York, and the language to be used in the proceedings shall be English;

 

  (ii)

the arbitrators shall, by majority vote, render a written award stating the reasons for their award within three (3) Months after any hearing conducted has been concluded. The arbitral award may contain such orders (including orders for specific performance, setoff, other equitable relief or monetary damages) in respect of or affecting any of the Parties (and/or any direct loss or damage suffered by any of them), as such arbitrators determine to be appropriate in the circumstances; provided that, except as expressly permitted by the terms of the Agreement, the arbitrators shall not have the authority to award any indirect, consequential or punitive damages;

 

  (iii)

the Parties and the arbitral tribunal will ensure that the arbitration proceedings and any documents disclosed in such proceedings are kept strictly confidential; and

 

  (iv)

the responsibility for the costs of the arbitration will be determined by the arbitral tribunal.

 

  (c)

An arbitral award rendered in accordance with this Clause 20.2 shall be final and binding on the Parties. The Parties agree that any arbitral award made pursuant to this Clause 20.2 may be enforced against the Parties or their assets wherever they may be found and that a judgment upon the arbitral award may be entered (and any other applicable relief, including interlocutory relief, may be granted) in any court having jurisdiction on such matters, and subject to their respective obligations contained elsewhere in the Agreement, shall take all such actions as are necessary to give full and complete effect to the award which, in accordance with its terms, shall be binding upon and enforceable against them. The Parties may make an application to any court for the obtaining of any evidence (whether by discovery of documents, interrogatories, affidavits or testimony of witnesses or whatsoever), which the arbitrators direct shall be admitted in the arbitral proceedings.

 

  (d)

No Party shall be entitled to suspend its performance under the Agreement during the pendency of any Dispute or during the period during which any defaulting Party is attempting to remedy its non-performance of the Agreement within the periods prescribed therefor in Clause 28.

 

A-54


  (e)

Nothing contained in this Clause 20 shall be construed to prohibit any Party from making an application to any court of competent jurisdiction for an order of specific performance or for other injunctive or equitable relief as long as the arbitral tribunal contemplated in Clause 20.2 has not yet been formed.

 

20.3

No Consolidation

Unless the Parties otherwise agree, no dispute, controversy or claim hereunder shall be consolidated with any other arbitration proceeding involving any third party.

 

21.

GOVERNING LAW

The validity, construction and performance of the Agreement shall be governed by and construed in accordance with the laws of the State of New York, without regard to the conflict of law provisions thereof that would require the application of the laws of any other jurisdiction.

 

22.

CONFIDENTIALITY

 

22.1

Confidential Information

In connection with the Agreement, each Party (as to information disclosed, the “Disclosing Party”) may each provide the other Party (as to information received, the “Receiving Party”) with Confidential Information. “Confidential Information” means:

 

  (a)

all pricing for Liquefaction Train System;

 

  (b)

all information that is designated in writing as “confidential” or “proprietary” by Disclosing Party at the time of written disclosure, except Work Product; and

 

  (c)

all information that is orally designated as “confidential” or “proprietary” by Disclosing Party at the time of oral disclosure and is confirmed to be “confidential” or “proprietary” in writing within ten (10) Days after oral disclosure, except Work Product.

Any Confidential Information disclosed or revealed by the Disclosing Party shall remain the Disclosing Party’s property and the Receiving Party shall not use such Confidential Information for its own benefit or for the benefit of any third party nor shall the Receiving Party disclose to any third party any such Confidential Information disclosed or revealed to it by the Disclosing Party, except as permitted under the Agreement. The Receiving Party shall take every reasonable precaution to protect the confidentiality of Confidential Information.

 

A-55


The obligations of this Clause 22.1 shall not apply as to any portion of the Confidential Information that:

 

  (i)

is or becomes generally available to the public other than from disclosure by Receiving Party, its representatives or its Affiliates;

 

  (ii)

is or becomes available to Receiving Party or its representatives or Affiliates on a non-confidential basis from a source other than Disclosing Party when the source is not, to the best of Receiving Party’s knowledge, subject to a confidentiality obligation to Disclosing Party;

 

  (iii)

is independently developed by Receiving Party, its representatives or Affiliates, without reference to the Confidential Information;

 

  (iv)

is required to be disclosed by Law, a valid legal process or a Governmental Authority;

 

  (v)

is approved for disclosure in writing by an authorized representative of Disclosing Party;

 

  (vi)

is disclosed by Seller to its Affiliates and each of their agents, advisors, employees, consultants, contractors, officers, directors and representatives (collectively, the “Seller’s Representatives”) to the extent necessary to evaluate the Facility and provided that each such Seller’s Representative is advised of the confidential nature of such Confidential Information and agrees to be bound by provisions consistent with the provisions of the Agreement or is bound by professional obligations of confidentiality;

 

  (vii)

is disclosed by Buyer to Owner, Owner’s Affiliates and each of their agents, advisors, employees, consultants, contractors, officers, directors, representatives, existing or potential investors, Lenders and existing or potential offtakers (and their respective consultants, advisors and agents) (collectively, the “Buyer’s Representatives”) to the extent necessary to evaluate the Facility and provided that each such Buyer’s Representative is advised of the confidential nature of such Confidential Information and agrees to be bound by provisions consistent with the provisions of the Agreement or is bound by professional obligations of confidentiality; or

 

  (viii)

is disclosed by Buyer or Owner to any Governmental Authority in connection with the Facility.

 

22.2

Restrictions on Use

Receiving Party agrees:

 

  (a)

to use the Confidential Information only as permitted under the Agreement;

 

A-56


  (b)

to take reasonable measures to prevent disclosure of the Confidential Information, except as permitted under the Agreement; and

 

  (c)

not to disclose the Confidential Information to any Person other than its Representatives.

Any Confidential Information disclosed or revealed by the Disclosing Party shall remain the Disclosing Party’s property. Receiving Party agrees to obtain a commitment from any recipient of Confidential Information to comply with the terms of this Clause 22. Confidential Information shall not be reproduced without Disclosing Party’s written consent, and upon expiration or termination of the Agreement, the Receiving Party shall return to the Disclosing Party all Confidential Information in its possession or control, except to the extent that the Agreement entitles Receiving Party to retain the Confidential Information; provided, however, that the return of such Confidential Information shall not affect the license rights granted to Buyer pursuant to Clause 18.

 

22.3

Disclosure

If Receiving Party or any of its Affiliates or Representatives is required to disclose any Confidential Information pursuant to Clause 22.1(iv), the Receiving Party agrees to provide Disclosing Party with prompt written notice to permit Disclosing Party to seek an appropriate protective order or agency decision or to waive compliance by Receiving Party with the provisions of this Clause 22. In the event that efforts to secure confidential treatment are unsuccessful, Receiving Party may, to the extent lawful, revise the Confidential Information to make it non-proprietary or to minimize the loss of its proprietary value.

 

22.4

No License

Nothing in Clause 22 grants Receiving Party any license to any invention, patent, trademark or copyright now or later owned or controlled by Disclosing Party.

 

22.5

Available Remedies

Each Party acknowledges that money damages would not be a sufficient remedy for a breach of this Clause 22. The Parties acknowledge that any violation of this Clause 22 by the Receiving Party may cause the Disclosing Party irreparable harm that could not be fully remedied by monetary damages. Accordingly, if it appears that the Receiving Party has disclosed (or has threatened to disclose) Confidential Information in violation of the Agreement, the Disclosing Party shall have the right, in addition to, and not in lieu of, monetary damages or any other legal or equitable remedy available to it, to seek injunctive or other equitable relief from a court of competent jurisdiction, without the necessity of proving damages or posting any bond, as may be necessary to prevent any such violation.

 

A-57


22.6

No Public Announcements

Neither Party shall make any public announcement about the Agreement or related documents, including its existence, without prior written approval of the other Party.

 

22.7

Survival

As to any individual item of Confidential Information, the restrictions of this Clause 22 shall expire upon the earlier of five (5) years following the date of disclosure or three (3) years following termination or expiration of the Agreement, except with respect to Confidential Information that the Disclosing Party protects as a trade secret, for which the obligations set forth in this Clause 22 shall remain in effect as long as such Confidential Information remains a trade secret.

 

23.

INSURANCE

 

23.1

Policy Coverages

Seller shall secure, pay for, and provide, at no additional cost or expense to Buyer, the following insurance coverages during the term of the Agreement:

 

TYPE

  

AMOUNT

  

OTHER REQUIREMENTS

1. Workers’ Compensation and Employer’s Liability    With respect to Workers’    1. No “alternative” forms of coverage will be permitted.
   Compensation:   
   Statutory Limits   
   With respect to Employer’s   
   Liability:   
   $ [***] Bodily Injury by   
   Accident – Each Accident   
   $ [***] Bodily Injury by   
   Disease – Policy Limit   
   $ [***] Bodily Injury by   
   Disease – Each Employee   
2. Commercial    $ [***] per occurrence    1. ISO form CG 0001 10/01 or equivalent.
General Liability    $ [***] product-completed
(Occurrence Basis)    operations aggregate limit.    2. Buyer will be named as “additional insured” (ISO CG2010 11/85 edition or equivalent and providing additional insured status for on-going and completed operations). This coverage on a primary and non-contributory basis.
   $ [***] personal and
   advertising injury limit.
   $ [***] aggregate
3. Business    Combined single limit for    1. ISO form CA 0001 1001, or equivalent.
Automobile    bodily injury and property   
Liability       

 

A-58


TYPE

   AMOUNT   

OTHER REQUIREMENTS

(Occurrence Basis)    damage of [***] per

occurrence or its equivalent.

   2. Buyer will be named as “additional insured”. This coverage on a primary and non- contributory basis.
         3. Includes owned, hired and non-owned vehicles.

4. Umbrella

Liability (Occurrence Basis)

   $    [***]    1. Written on an umbrella basis above the coverage referenced above.
         2. Same inception and expiration dates as commercial general liability insurance.
         3. Waiver of subrogation in favor of Buyer.

5. Professional

Liability

(Claims-Made

Basis)

   $    [***] per claim /    1. No exclusion for bodily injury, property damage, asbestos or pollution liability (including mold).
   $    [***] annual aggregate
         2. Coverage must remain in place for a minimum of two (2) years after the date of Substantial Completion of the Facility.

6. Marine Cargo

Insurance

   [Highest value individual    1. Inception from the time shipment first set in motion at Seller’s premises for imminent transit to the Site
   shipment]
         2. No co-insurance clause.
         3. Buyer will be named as “additional insured”

7. Personal

Property Insurance

   [Amount at/exceeding value of equipment being purchased]    1. Seller shall cause the Person designated by Buyer to be duly designated, by means of amendments by endorsement in form and substance satisfactory to Buyer, to be first loss payee.

 

23.2

Certificates of Insurance

All commercial general liability and automobile liability insurance coverage shall be written on an occurrence-based or claims-made form. An original certificate of insurance in the accord form shall be delivered to Buyer and Owner within five (5) Days of the date of the Agreement, prior to commencement of performance under the Agreement or prior to the payment of any amounts by Buyer hereunder, whichever occurs first. The certificate of insurance shall evidence insurance coverage at least in the minimum limits, or as may

 

A-59


be further increased in connection with the requirements of the Agreement and contain an endorsement affording thirty (30) Days prior written notice to Buyer and Owner by certified mail in the event of cancellation or non-renewal of coverage and ten (10) Days written notice to Buyer and Owner by certified mail in the event of nonpayment of the premium.

 

23.3

Additional Insureds

At no expense to Buyer, Seller shall name Buyer and other Buyer Parties (as such are reasonably designated by Buyer) as an additional insured to the extent of Seller’s obligations under the Agreement on all liability insurance policies required hereunder (other than Professional Liability and Employer’s Liability insurance). Seller acknowledges Seller’s obligation to obtain appropriate insurance coverages for the benefit of Seller (and Seller’s employees, if any). If Seller fails to comply with the obligations for insurance required herein, Buyer shall have the right, but not the obligation, to purchase such insurance at Seller’s sole cost and expense and shall invoice, withhold payment or back charge Seller for the cost incurred by Buyer to satisfy such obligations. Seller waives any rights to recovery from Buyer for any injuries that Seller (and/or Seller’s employees) may sustain while performing Seller’s obligations under the Agreement and that are a result of the negligence of Seller or Seller’s employees. Likewise, Buyer waives any rights to recovery from Seller for any injuries that Buyer (and/or Buyer’s employees) may sustain while performing Buyer’s obligations under the Agreement and that are a result of the negligence of Buyer or Buyer’s employees.

 

23.4

Buyer/Owner All-Risk Insurance

At no expense to Seller, from and after Financial Closing, Buyer shall cause a Builder’s All-Risk insurance policy (“BAR Policy”) to be maintained in a coverage amount sufficient to cover the construction, commissioning, and testing of the Facility. Seller shall receive a waiver of subrogation to the extent of Buyer’s and Owner’s release and indemnity obligations contained in the Agreement.

 

24.

CHANGE ORDERS

 

24.1

Buyer Change Order

Buyer may, at any time, by written notice to Seller, request an addition to, or deletion from, or other changes in obligations of Seller under Appendix C (Scope of Supply & Project Schedule) and/or items and Deliverables that are to be provided by Seller hereunder, including alterations to the Liquefaction Train System schedule or scope. Seller shall review and reasonably consider such requested change and shall make a written response concerning such change to Buyer within ten (10) Days after receiving such request from Buyer to confirm if Seller will pursue cost and schedule analysis. Within twenty (20) Days of the requested change Seller, will provide a written response to include Seller’s estimated lump-sum fixed cost associated with such requested change together with the estimated number of hours, average hourly rates and material quantities required to carry out such change. If the Parties agree upon such change, the Parties shall set forth the agreed-upon change in a written change order signed by all Parties in the form of Appendix I (a “Change Order”). Each Change Order shall constitute a final accord, satisfaction and settlement of all matters covered therein.

 

A-60


24.2

Seller Change Order

To the extent that (a) Seller experiences a Force Majeure Event or (b) a suspension is requested by Buyer in accordance with Clause 29.3, or (c) other circumstances occur which specifically entitle Seller to request a Change Order under the Agreement, if Seller desires to request an equitable adjustment to the Project Schedule and/or Contract Price, Seller shall give Buyer notice within fifteen (15) Days after Seller knows of the occurrence of the event or circumstances giving rise to such request. Within fifteen (15) Days after the delivery of such notice, Seller shall provide Buyer with a written notice setting forth the reasons why Seller believes the Project Schedule or Contract Price should be adjusted and the requested adjustment to the Project Schedule or Contract Price, such written response to include Seller’s estimated lump-sum fixed cost associated with such requested change together with the estimated number of hours and material quantities required to carry out such change. If Buyer does not agree with such requested adjustment, then Buyer shall notify Seller and such disagreement shall be resolved pursuant to the procedures set forth in Clause 20. If Buyer accepts any such requested adjustment to the Project Schedule or Contract Price, a Change Order shall be executed by the Parties and the Project Schedule or Contract Price shall be adjusted in accordance with the terms of such Change Order.

 

24.3

No Interruption of Performance

Except insofar as a Change Order was to specifically modify one or more provisions or conditions of the Agreement, all other provisions and conditions of the Agreement shall remain unaffected. No Change Order shall be deemed issued, or agreed upon, due to a course of dealing or course of the performance of any obligations hereunder, including the performance of any obligations pursuant to any other Change Order, individually or collectively. Seller shall not commence to perform, or perform, any obligations constituting a change from the obligations hereunder, and Buyer shall have no liability to Seller for any such obligations performed, unless Seller and Buyer have executed a Change Order. Seller shall not suspend, in whole or in part, performance of the Agreement during any dispute over any Change Order or a request for a Change Order unless directed to do so by Buyer, provided that Seller shall not be obligated to proceed with a disputed requested change or a disputed item under a Change Order, until such dispute is resolved, unless (a) such disputed requested change(s) or disputed item(s) (i) have an aggregate value of less than [***] or (ii) is required to address health and safety or environmental issues or (b) Seller elects, at its discretion, to proceed with such disputed requested change or disputed item while the dispute is still pending, provided, further, that, in each such case, Seller shall proceed, without waiving any rights with respect to such disputed requested change or disputed item.

 

A-61


25.

PERFORMANCE GUARANTEES, PERFORMANCE TESTS AND PERFORMANCE LIQUIDATED DAMAGES

 

25.1

Performance Guarantees

Seller guarantees to Buyer that the following Performance Guarantees shall be satisfied in accordance with Appendix F (Performance Tests):

 

  (a)

the LNG production capacity (measured in MTPA) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be equal to or greater than the Liquefaction Train Production Capacity Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train;

 

  (b)

the LNG production capacity (measured in lbs/hr) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be equal to or greater than the Liquefaction Train System Production Capacity Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date;

 

  (c)

(i) the minimum performance guarantee with respect to power demand (measured in kWh/Tonne) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train Power Demand Minimum Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train; and

(ii) the full performance guarantee with respect to power demand (measured in kWh/Tonne) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train Power Demand Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train;

 

  (d)

(i) the minimum performance guarantee with respect to power demand (measured in kWh/Tonne) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train System Power Demand Minimum Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date; and

 

A-62


(ii) the full performance guarantee with respect to power demand (measured in kWh/Tonne) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train System Power Demand Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date;

 

  (e)

the full performance guarantee with respect to any loss in Mixed Refrigerant (measured in standard liters/minute) for the Liquefaction Train System, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Refrigerant Losses Performance Guarantee prior to shipment from the manufacturing facility;

 

  (f)

the quality of the LNG produced by the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall satisfy the LNG Quality Performance Guarantee, on or before the Guaranteed Liquefaction Train System Substantial Completion Date; and

 

  (g)

The Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, will run at the required capacity to meet Facility demand over a [***] hour continuous test period with [***] equivalent availability factor that accounts for any capacity de-ratings during the test period (the “Reliability Guarantee”). Seller shall have a maximum of [***] test periods allotted to satisfy the Reliability Guarantee before a change of equipment or software is required. The Performance Test for the Reliability Guarantee will be run concurrently with tests in Clause 25.1(b).

 

25.2

Performance Tests

Seller shall conduct in accordance with Appendix F (Performance Tests) (a) the Liquefaction Train Performance Tests for an individual Liquefaction Train only after such Liquefaction Train has achieved Ready for Test and (b) the Liquefaction Train System Performance Tests only after the Liquefaction Train System has achieved Ready for Test. Seller shall conduct the Performance Tests for each of the Liquefaction Trains, individually, and the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, under the conditions and in strict accordance with the requirements set forth in Appendix F (Performance Tests). If (A) the Liquefaction Train Performance Tests of an individual Liquefaction Train demonstrate that the Liquefaction Train Performance Guarantees for such Liquefaction Train System have been achieved or (B) the Liquefaction Train System Performance Tests demonstrate that the Liquefaction Train System Performance Guarantees have been achieved, then Seller shall provide Buyer with written notice of such occurrence and shall provide Buyer with a test report, together with supporting documentation, demonstrating the achievement of the applicable Performance Guarantees within ten (10) Days of the date of the completion of such Performance Tests and upon receipt of such documentation Buyer shall, within ten (10) Days, either (A) confirm in writing to Seller the successful completion of the Liquefaction Train Performance Tests or the Liquefaction Train System Performance Tests or (B) provide written notice to Seller of why Buyer disagrees that the Liquefaction Train

 

A-63


Performance Guarantees or the Liquefaction Train System Performance Guarantees have been achieved. If any Performance Test indicates that an individual Liquefaction Train or the Liquefaction Train System fails to achieve any Performance Guarantee for reasons attributable to Seller, its Affiliates or Subcontractors, then Seller shall, at its own cost and expense, take appropriate corrective action and Seller shall thereafter reperform the Performance Test.

Seller’s obligation to meet the Liquefaction Train Performance Guarantees under this Clause 25 shall be satisfied when (i) all the Liquefaction Train Performance Tests have been completed, and (ii) either (1) such tests demonstrate that all Liquefaction Train Performance Guarantees are met or (2) such tests demonstrate that the Liquefaction Train Power Demand Minimum Performance Guarantee is met and Seller has paid all payable liquidated damages for the Liquefaction Train Performance Guarantees that are not met.

Seller’s obligation to meet the Liquefaction Train System Performance Guarantees under this Clause 25 shall be satisfied when (i) all the Liquefaction Train System Performance Tests have been completed, and (ii) either (1) such tests demonstrate that all Liquefaction Train System Performance Guarantees are met or (2) such tests demonstrate that the Liquefaction Train Power Demand Minimum Performance Guarantee and the Refrigerant Losses Performance Guarantee are met and Seller has paid all payable liquidated damages for the Liquefaction Train System Performance Guarantees that are not met.

At all times during start-up, testing and commissioning of the Liquefaction Train System, Owner may, at no expense to Seller, arrange for the disposition of the Facility’s LNG. Owner shall have all right, title and interest to all LNG produced by the Facility and all of the proceeds from the sale thereof.

 

25.3

Performance Liquidated Damages and Performance Delay Liquidated Damages

(a) Performance Liquidated Damages

 

  (i)

If Seller achieves the Liquefaction Train Power Demand Minimum Performance Guarantee but fails to achieve the Liquefaction Train Power Demand Performance Guarantee for a Liquefaction Train, then Seller shall pay to Buyer [***] [***] Dollars [***] for each kWh/Tonne of LNG produced above the Liquefaction Train Power Demand Performance Guarantee (the “Liquefaction Train Power Demand Liquidated Damages”).

 

  (ii)

If Seller achieves the Liquefaction Train System Power Demand Minimum Performance Guarantee but fails to achieve the Liquefaction Train System Power Demand Performance Guarantee, then Seller shall pay to Buyer [***] Dollars [***] for each kWh/Tonne of LNG produced above the Liquefaction Train System Power Demand Performance Guarantee (the “Liquefaction Train System Power Demand Liquidated Damages”).

 

A-64


  (iii)

The total amount of Performance Liquidated Damages payable by Seller to Buyer shall not exceed the Performance Liquidated Damages Cap and the total amount of Liquidated Damages payable by Seller to Buyer shall not exceed the Liquidated Damages Cap. Once Seller has accrued (i) Performance Liquidated Damages in amount equal to the Performance Liquidated Damages Cap or (ii) Liquidated Damages in amount equal to the Liquidated Damages Cap, [***].

 

  (iv)

The assessment of Liquefaction Train Power Demand Liquidated Damages will not apply concurrently with Liquefaction Train System Power Demand Liquidated Damages.

(b) Performance Delay Liquidated Damages

 

  (i)

If Seller fails to achieve the Liquefaction Train Production Capacity Performance Guarantee for a Liquefaction Train on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train, then Seller shall pay to Buyer an amount equal to: (x) in respect of the first [***] Liquefaction Trains to be performance tested, (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each Day of such delay for the next [***]; and (y) in respect of the subsequent [***] Liquefaction Trains to be performance tested, (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] [***] Dollars ( [***] ) per Day for each Day of such delay for the next [***] (the “Liquefaction Train Production Capacity Liquidated Damages”).

 

  (ii)

If Seller fails to achieve either the Liquefaction Train System Production Capacity Performance Guarantee, or the LNG Quality Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date, then Seller shall pay to Buyer an amount equal to (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] Dollars ( [***] ) per Day for each Day of such delay for the next [***] (the “Liquefaction Train System Production Capacity Liquidated Damages” or the “LNG Quality Liquidated Damages”, as applicable).

 

  (iii)

The aggregate amount of Performance Delay Liquidated Damages payable by Seller to Buyer for each Liquefaction Train shall not exceed the applicable Performance Delay Liquidated Damages Cap. The aggregate amount of Liquefaction Train System Production Capacity Liquidated Damages and LNG

 

A-65


  Quality Liquidated Damages payable shall not exceed, in the aggregate, the Liquefaction Train System Performance Delay Liquidated Damages Cap. Once Seller has accrued (i) Performance Delay Liquidated Damages in amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (ii) Liquidated Damages in amount equal to the Liquidated Damages Cap, [***].

 

  (c)

Buyer shall invoice Seller on a monthly basis for any amounts due for Performance Liquidated Damages and Performance Delay Liquidated Damages. Payment of any Performance Liquidated Damages and Performance Delay Liquidated Damages by Seller shall occur within ten (10) Business Days following the date Buyer submits to Seller an invoice therefore. Buyer and Seller agree that the amount of Performance Liquidated Damages and Performance Delay Liquidated Damages are reasonable in light of the anticipated harm caused by the breach of duty related thereto and the difficulties of proof of loss and inconvenience or non-feasibility of obtaining any adequate remedy with respect to the actual level of damages Buyer is likely to suffer in the event that Seller fails to achieve the (i) Liquefaction Train Power Demand Performance Guarantee, (ii) Liquefaction Train System Power Demand Performance Guarantee, or (iii)(A) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (B) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, and the Parties are estopped from contesting the validity or enforceability of such liquidated damages. Except as provided in Clause 28.1 and Clause 28.3, the payment of Performance Delay Liquidated Damages shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for Seller’s failure to achieve (w) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (x) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date. Except as provided in Clause 28.1 and Clause 28.3, the payment of Performance Liquidated Damages shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for Seller’s failure to achieve (y) the Liquefaction Train Power Demand Performance Guarantee or (z) the Liquefaction Train System Power Demand Performance Guarantee. In the event the Performance Liquidated Damages or Performance Delay Liquidated Damages provisions are found for any reason to be void, invalid or otherwise inoperative so as to disentitle Buyer from claiming and recovering Performance Liquidated Damages or Performance Delay Liquidated Damages from Seller, Buyer shall, in addition to the remedies set forth below in Clause 25.4, be entitled to claim against Seller and recover for damages for Seller’s failure to achieve (1) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train, (2) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, (3) Liquefaction Train Power Demand Performance Guarantee or (4)

 

A-66


  Liquefaction Train System Power Demand Performance Guarantee; provided that such damages shall not exceed, in the case of Clauses (1) and (2), the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, and, in the case of Clauses (3) and (4), the Performance Liquidated Damages Cap.

 

25.4

Buyer Remedies

If Seller has accrued an aggregate amount of (i) Performance Liquidated Damages in an amount equal to the Performance Liquidated Damages Cap, (ii) Performance Delay Liquidated Damages in an amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (iii) Liquidated Damages in an amount equal to the Liquidated Damages Cap, then Buyer may by notice to Seller, at Buyer’s sole discretion, either:

 

  (a)

 [***]

 

  (b)

 [***]

 

25.5

Performance Guarantees [***]

Seller acknowledges and agrees that its Unconditional Performance Obligation is [***].

 

A-67


26.

ACCESS AFTER DELIVERY

For the sole purpose of (and to the extent necessary for) performing its obligations under the Agreement regarding the remedying of Defects or guaranteed performance, Seller may request Buyer (who shall not unreasonably withhold its consent) to have the right of access to all parts of the Liquefaction Train System(s). Such access shall only be granted during normal working hours and will be limited to the duly authorized representatives of Seller, provided that (a) Seller shall, and shall cause its authorized agents, employees and inspectors to, at all times comply with Buyer’s safety and security requirements when present at the Site and (b) Seller shall not, and shall cause its authorized agents, employees and inspectors not to, interfere with the operation of any Liquefaction Train System or the Facility. Seller understands and acknowledges that the Liquefaction Trains will commence commercial operations prior to the Substantial Completion of the Facility.

 

27.

QUALITY ASSURANCE AND QUALITY CONTROL

The quality control exercised by Seller in its manufacture of the Liquefaction Train System shall be in accordance with the standards set forth in Appendix E (Quality Assurance and Quality Control).

 

28.

EVENTS OF DEFAULT; REMEDIES

 

28.1

Events of Default for Seller

Each of the following events constitutes an Event of Default of Seller under the Agreement:

 

  (a)

Seller fails to make when due any payment (other than amounts disputed in good faith) due and owing under the Agreement and such failure is not cured within ten (10) Working Days after Buyer notifies Seller of such failure;

 

  (b)

Seller is in material breach of its obligations under the Agreement (other than an obligation to make payment or an obligation that is otherwise specifically set forth in this Clause 28.1 as a separate Event of Default) and such material breach is not remedied within thirty (30) Days after Buyer notifies Seller of such material breach, which notice sets forth in reasonable detail the nature of such material breach, provided that if such material breach is not reasonably capable of being remedied within the thirty (30) Day remedy period specified above but is reasonably capable of being remedied, Seller shall have an additional sixty (60) Day remedy period to remedy such material breach, so long as Seller promptly commences and thereafter diligently pursues such remedy;

 

  (c)

Seller fails to establish or maintain the credit support required under Clause 7.9, and such breach is not cured within ten (10) Working Days after written notice of such breach from Buyer;

 

A-68


  (d)

Any representation or warranty made by Seller in Clause 32.2 is not true in all material respects as of the date made and such inaccuracy is not cured within thirty (30) Days after Buyer notifies Seller of such inaccuracy, which notice sets forth in reasonable detail the nature of the inaccuracy;

 

  (e)

A Bankruptcy Event occurs with respect to Seller;

 

  (f)

Seller assigns the Agreement, except as described in Clause 4.1;

 

  (g)

If Seller has accrued an aggregate amount of Delivery Delay Liquidated Damages in an amount equal to the Delivery Delay Liquidated Damages Cap or Aggregate Delivery Delay Liquidated Damages Cap, as applicable, and has not delivered all of the Liquefaction Trains (in their entirety) to the Delivery Point; and

 

  (h)

If Seller has accrued an aggregate amount of (i) Performance Liquidated Damages in an amount equal to the Performance Liquidated Damages Cap, (ii) Performance Delay Liquidated Damages in an amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (iii) Liquidated Damages in an amount equal to the Liquidated Damages Cap and Seller has failed to achieve (A) the Liquefaction Train Performance Guarantees for any Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (B) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, (C) Liquefaction Train Power Demand Performance Guarantee or (D) Liquefaction Train System Power Demand Performance Guarantee.

If an Event of Default with respect to Seller has occurred, Buyer will have the right, but not the obligation, at any time when such Event of Default is continuing, to designate by notice to Seller a date for terminating the Agreement that will be no earlier than thirty (30) Days after the notice is deemed delivered. Upon the date designated as the termination date by Buyer as a result of an Event of Default of Seller, Buyer shall suspend any further payment to Seller under the Agreement.

 

28.2

Events of Default for Buyer

Each of the following events constitutes an Event of Default of Buyer under the Agreement:

 

  (a)

Buyer fails to make when due any payment (other than amounts disputed in good faith) due and owing under the Agreement and such failure is not cured within ten (10) Working Days after Seller notifies Buyer of such failure;

 

A-69


  (b)

Buyer is in material breach of its obligations under the Agreement (other than an obligation to make payment or an obligation that is otherwise specifically set forth in this Clause 28.2 as a separate Event of Default) and such material breach is not remedied within thirty (30) Days after Seller notifies Buyer of such material breach, or if such material breach cannot be reasonably remedied within such thirty (30) Day period, Buyer has not commenced to cure such material breach within thirty (30) Days of notice from Seller, which notice sets forth in reasonable detail the nature of such material breach, provided that if such material breach is not reasonably capable of being remedied within the thirty (30) Day remedy period specified above but is reasonably capable of being remedied, Buyer shall have an additional sixty (60) Day remedy period to remedy such material breach, so long as Buyer promptly commences and thereafter diligently pursues such remedy;

 

  (c)

Buyer fails to establish or maintain the credit support as required by Clause 7.8 and such breach is not cured within ten (10) Working Days after written notice of such breach from Seller;

 

  (d)

Any representation or warranty made by Buyer in Clause 32.1 is not true in all material respects as of the date made and such inaccuracy is not cured within thirty (30) Days after Seller notifies Buyer of such inaccuracy, which notice sets forth in reasonable detail the nature of the inaccuracy;

 

  (e)

A Bankruptcy Event occurs with respect to Buyer; and

 

  (f)

Buyer assigns the Agreement, except as described in Clause 4.1.

If an Event of Default with respect to Buyer has occurred, Seller will have the right, but not the obligation, at any time when such Event of Default is continuing, to designate by notice to Buyer a date for terminating the Agreement that will be no earlier than thirty (30) Days after the notice is deemed delivered. Upon the date designated as the termination date by Seller as a result of an Event of Default of Buyer, Seller shall (i) terminate performance of its obligations under the Agreement; and (ii) invoice Buyer in connection with any obligations performed under the Agreement for which Seller has not received payment by Buyer.

 

28.3

Remedies

Upon any termination of the Agreement (including by Buyer under Clause 6.5(b) or Clause 29.1), Seller shall deliver to Buyer the portions of the Liquefaction Train System for which Seller has received payment and which have not been delivered to the Delivery Point. Except where exclusive and/or sole remedies are expressly provided herein, (a) remedies available to each Party under the Agreement are cumulative and (b) whether or not the Agreement is terminated in accordance with this Clause 28, each Party may assert any claims under the Agreement, at law or in equity against the other Party for damages incurred by such Party resulting from any breach of, or default under, the Agreement by the other Party; but the Parties agree that such remedies and claims for damages incurred by such Party resulting from any breach of, or default under, the Agreement by the other Party are always subject to the (i) limitations and exclusions of liability and (ii) dispute resolution provisions provided for in the Agreement; provided, further, that the Delivery

 

A-70


Delay Liquidated Damages Cap, Aggregate Delivery Delay Liquidated Damages Cap, the Aggregate Performance Delay Liquidated Damages Cap, the Performance Delay Liquidated Damages Cap, the Liquefaction Train System Performance Delay Liquidated Damages Cap, the Performance Liquidated Damages Cap and the Liquidated Damages Cap shall not be construed to limit either Party’s liability hereunder upon a termination of the Agreement. Each Party agrees that it has a duty to mitigate Costs and covenants that it will use commercially reasonable efforts to minimize any Costs, including termination Costs that it may incur as a result of the other Party’s performance or non-performance hereof. Neither the termination nor expiration of the Agreement will relieve either Party of: (i) any undischarged liability of such Party in respect of the period prior to such termination or expiration (including for unpaid amounts owing under the Agreement in respect of the period prior to such termination or expiration, including payments due as a result of events occurring prior to such termination or expiration); or (ii) any liability for breach by such Party of the Agreement.

 

29.

TERMINATION AND SUSPENSION

 

29.1

Termination by Buyer

Buyer may at any time terminate the Agreement for its convenience by giving Seller [***] written notice of termination, but subject to payment of the Termination Fees in accordance with Clause 29.2. The Agreement shall terminate with effect from the date indicated in such notice.

 

29.2

Termination Fee

In the event of a termination by Buyer under Clause 29.1, Buyer shall pay to Seller the applicable termination payment, as determined in accordance with Appendix B (Pricing; Payment Terms & Cancellation Schedule) (the “Termination Fee”), provided that under no circumstances shall the Termination Fee exceed the applicable maximum Termination Fee set forth in the table in Appendix B (Pricing; Payment Terms & Cancellation Schedule) (the “Maximum Termination Fee”). The Termination Fee, if any, shall be paid within thirty (30) Days from Seller’s invoice therefor. The Termination Fee, if any, shall be Seller’s sole and exclusive remedy and Buyer’s sole and exclusive liability for a termination of the Agreement by Buyer for Buyer’s convenience. Buyer and Seller agree that the Termination Fee represents an accurate, reasonable and conservative estimate of the actual level of damages Seller is likely to suffer in the event of such Termination.

 

29.3

Order to Suspend Execution of the Agreement

 

  (a)

Buyer may at any time, upon thirty (30) Days’ prior written notice, instruct Seller to suspend the performance of Seller’s obligations under the Agreement or any portion thereof for such time and in such manner as Buyer may reasonably consider necessary. Upon receiving any such notice of suspension, Seller shall: (i) properly protect and secure the Liquefaction Train System against any deterioration, loss or damage, as considered necessary or required by Buyer; (ii) place no further

 

A-71


purchase orders or subcontracts for materials, services or facilities with respect to the suspended performance; (iii) promptly make every reasonable effort to obtain suspension, with terms satisfactory to Buyer of all subcontracts with all Subcontractors to the extent they related to the suspended performance; and (iv) take any other reasonable steps to minimize costs and expenses associated with such suspension.

 

  (b)

Any Costs reasonably incurred and properly documented by Seller (including, but not limited to, demobilization, remobilization, storage, preservation, inspection, related labor and any other costs due to such suspension) in giving effect to Buyer’s suspension instructions under this Clause 29.3, shall be borne and paid by Buyer, or, unless such suspension is (i) necessary by reason of a breach or Event of Default on the part of Seller or (ii) due to a Force Majeure Event.

 

  (c)

If Buyer is in breach of its obligation to timely pay undisputed amounts owed to Seller under the Agreement, Seller may suspend immediately upon written notice to Buyer, without penalty and without further proof or establishment of cause, the performance of Seller’s obligations until such undisputed payment is made by Buyer. Seller shall be entitled to request a Change Order for an equitable adjustment of the Project Schedule to the extent that such Seller suspension adversely affects the delivery of any Liquefaction Train in accordance with the Project Schedule. Any Costs reasonably incurred and properly documented by Seller in accordance with such suspension (including storage, demobilization and re-mobilization costs) shall be payable by Buyer within thirty (30) Days of receipt of Seller’s invoices, provided Seller shall exercise commercially reasonable efforts to mitigate and minimize such Costs.

 

29.4

Resumption of Works

At any time after a suspension under Clause 29.3, Buyer may give written notice to Seller to proceed with the delivery of the Liquefaction Trains and/or with the execution of all or part of the Agreement suspended under this Clause 29. Seller will be entitled to a Change Order to equitably adjust the Contract Price and the Project Schedule prior to resuming performance.

 

29.5

Prolonged Suspension

If the performance of Seller’s obligations under the Agreement or any portion thereof is suspended pursuant to Clause 29.3 and if notice to resume execution is not given by Buyer within [***] , then Seller may serve notice in writing to Buyer requesting permission to proceed with the Agreement or the portion in regard to which progress is suspended. If such permission to proceed is not granted by Buyer within [***] of Buyer’s receipt of such notice, either Party may, by a further prior written notice to the other Party, elect to terminate the Agreement. Seller shall transfer or assign to Buyer, title in the part of the Liquefaction Train System for which payment has been received in full as of the date of any termination of the Agreement. This Clause 29.5 shall not apply if the suspension was (i) necessary by reason of some material default on the part of Seller or (ii) due to a Force Majeure Event.

 

A-72


30.

GENERAL CLAUSES

 

30.1

No Third Party Beneficiary

The Parties expressly agree that Owner shall be a third party beneficiary of the Agreement entitled, in its own name, in the name of Buyer or in the name of any assignee of Buyer to enforce the Agreement against Seller (subject to such enforcement being subject to all the limitations, exclusions, remedies and defenses provided to Seller under the Agreement). Except as provided in the foregoing sentence with respect to Owner and in Clause 18.8, Clause 19.2 and Clause 19.3 with respect to the Buyer Parties and the Seller Parties, the provisions of the Agreement are for the benefit of the Parties hereto and not for any other third party. The Agreement shall be binding upon and inure to the benefit of each of the Parties and their respective successors and permitted assigns.

 

30.2

Severability

Should a determination be made by a court of competent jurisdiction that any provision of the Agreement is illegal, invalid or otherwise unenforceable, the same shall not affect the other terms or provisions of the Agreement, but such provisions shall be deemed modified to the extent necessary in the court’s opinion to render such term or provision enforceable, and the rights and obligations of the Parties shall be construed and enforced accordingly, preserving to the fullest extent possible the intent and agreements of the Parties set forth herein.

 

30.3

Counterparts

The Agreement may be executed in one or more counterparts, each of which shall be deemed an original, but all of which taken together shall constitute one and the same instrument. Signatures may be delivered electronically or by facsimile, and such copies shall be treated as originals for all purposes.

 

30.4

Attorney Review

The Parties acknowledge that each Party and its attorney have reviewed the Agreement and that any rule of construction to the effect that any ambiguities are to be resolved against the drafting Party, or any similar rule operating against the drafter of an agreement, shall not be applicable to the construction or interpretation of the Agreement.

 

30.5

Time is of the Essence

Time is of the essence in the performance of the Agreement.

 

A-73


30.6

No Waiver

The waiver by a Party of a breach of any provision of the Agreement by the other Party shall not be construed as a waiver of any succeeding breach of the same or any other provision, nor shall any delay or omission on the part of a Party to exercise or avail itself of any right, power or privilege that it has, or may have, hereunder operate as a waiver of any right, power or privilege by such Party. Any consent or permission granted under the Agreement shall be effective only in the specific instance and for the specific purpose given.

 

30.7

Survival

Upon termination of the Agreement, the rights and obligations of the Parties hereunder shall terminate, except for: (i) provisions that are indicated herein as surviving and those provisions that by their nature are intended to survive; and (ii) rights and obligations accrued as of the date of termination and in connection therewith.

 

30.8

Relationship to Second Phase

The Parties acknowledge and agree that the Second LTS Purchase Order is an independent agreement between the Parties and, notwithstanding anything contained herein to the contrary, the Agreement shall not be construed to interpret or modify, or otherwise challenge the enforceability of or invalidate, the Second LTS Purchase Order.

 

31.

HAZARDOUS MATERIALS

 

31.1

Hazardous Materials

Seller shall, and shall cause all of its Subcontractors to, comply with all applicable Laws relating to Hazardous Materials. If Seller is performing any of its obligations hereunder at the Site, Seller shall not, nor shall it permit any Subcontractor to, bring, introduce, use or release any Hazardous Material on or at the Site. Seller shall be responsible for the management, storage, disposal, removal, treatment and/or remediation of any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site. In addition, Seller shall not, and shall cause its Subcontractors to not, take any action or fail to take any action, that may disrupt, release or exacerbate, or render more costly the removal or remediation of, any Hazardous Materials existing on the Site prior to the date Seller commences the performance of its obligations hereunder on the Site. Seller shall indemnify, defend, release and hold harmless the Buyer Parties from any costs, expenses or liability resulting from any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site, to the extent resulting from Seller’s or its Subcontractors’ fault, negligence (in any form) or willful misconduct. Buyer shall indemnify, defend, release and hold harmless the Seller Parties from any costs, expenses or liability resulting from any Hazardous Material use or releases on or at the Site, excluding any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site.

 

A-74


31.2

Notification

If Seller encounters a condition at the Site involving a Hazardous Material or if Seller or anyone for whom Seller is responsible creates a condition involving a Hazardous Material, Seller shall promptly: (a) secure or otherwise isolate such condition, (b) stop its performance of its obligation hereunder in connection with such condition and in any area affected thereby and not take any action that may disrupt, release or exacerbate any such condition, and (c) verbally notify Buyer (and promptly thereafter confirm such notice of such condition in writing). Seller shall cooperate with and assist Buyer in making the Site available for the taking of necessary remedial steps.

 

32.

REPRESENTATIONS AND WARRANTIES

 

32.1

Buyer Representations and Warranties

Buyer hereby represents and warrants to Seller that as of the Effective Date: (a) Buyer is a limited liability company duly organized, validly existing and in good standing under the laws of its state of organization and has all requisite limited liability company power and authority to own and operate its properties and assets and to carry on its business as now conducted; (b) Buyer is duly qualified and is authorized to transact business and is in good standing as a foreign organization in each jurisdiction in which the failure so to qualify would have a material adverse effect on its ability to perform its obligations under the Agreement; (c) all limited liability company action on its part and on the part of its officers, managers and/or members necessary for the authorization, execution and delivery of the Agreement and the performance by it of all of its obligations hereunder have been taken; (d) it has obtained all governmental approvals or third party approvals required for the performance by it of its obligations under the Agreement; (e) there is no action pending or, to its knowledge, currently threatened against it that seeks to prohibit the transactions contemplated by the Agreement or adversely affect its ability to perform under the Agreement; and (f) the Agreement constitutes the legal, valid and binding obligation of Buyer, enforceable in accordance with its terms (subject to principles of equity, the effect of bankruptcy, insolvency, reorganization, receivership, moratorium, and other similar laws), and the execution, delivery and performance of the Agreement by Buyer does not and will not, in any material respect, conflict with, violate or cause a breach of any applicable Law, material agreement, contract or instrument to which Buyer is a party or any judgment, order or decree to which Buyer is subject.

 

32.2

Seller Representations and Warranties

Seller hereby represents and warrants to Buyer that as of the Effective Date: (a) Seller is a limited liability company duly organized, validly existing and in good standing under the laws of its state of organization and has all requisite limited liability company power and authority to own and operate its properties and assets and to carry on its business as now conducted; (b) Seller is duly qualified and is authorized to transact business and is in good standing as a foreign organization in each jurisdiction in which the failure so to qualify would have a material adverse effect on its ability to perform its obligations under the

 

A-75


Agreement; (c) all limited liability company action on its part and on the part of its officers, managers and/or members necessary for the authorization, execution and delivery of the Agreement and the performance by it of all of its obligations hereunder have been taken; (d) it has obtained all governmental approvals or third party approvals required for the performance by it of its obligations under the Agreement; (e) there is no action pending or, to its knowledge, currently threatened against it that seeks to prohibit the transactions contemplated by the Agreement or adversely affect its ability to perform under the Agreement; (f) the Agreement constitutes the legal, valid and binding obligation of Seller, enforceable in accordance with its terms (subject to principles of equity, the effect of bankruptcy, insolvency, reorganization, receivership, moratorium, and other similar laws), and the execution, delivery and performance of the Agreement by Seller does not and will not, in any material respect, conflict with, violate or cause a breach of any applicable Law, material agreement, contract or instrument to which Seller is a party or any judgment, order or decree to which Seller is subject.

 

33.

FORCE MAJEURE

 

33.1

Force Majeure Event

 

  (a)

Each Party shall not be liable or be considered to be in breach or default of its obligations under the Agreement to the extent that performance of such obligations is delayed or prevented, by a Force Majeure Event. A “Force Majeure Event” means any cause or event, or any combination of any causes or events, that: (i) is unforeseeable; (ii) is beyond the reasonable control and without fault or negligence of the affected Party; (iii) could not have been prevented in whole or in part by the exercise of reasonable care and skill by the affected Party; and (iv) materially impairs or prevents the performance of obligations under the Agreement by the affected Party. Subject to the requirements of the preceding sentence, Force Majeure Events may include, but are not limited to, acts of God or the public enemy, acts (or omissions) of Governmental Authorities, fires, severe weather conditions, earthquakes, strikes or other labor disturbances, floods, war (declared or undeclared), armed conflict, acts or threats of terrorism, epidemics (including the pandemic known as COVID-19), civil unrest, riot, delays or interruptions of or by any Governmental Authority of the Country or of any other governments having jurisdiction, embargoes or quarantines. The Parties acknowledge that this Agreement reflects the impact of the COVID-19 epidemic as of the Effective Date. To the extent new adverse circumstances pertaining to the COVID-19 epidemic arise after the Effective Date, each Party shall continue to work in good faith to mitigate any resulting impact, and shall be entitled, if and to the extent applicable, to relief in accordance with this Clause 33.

 

  (b)

For the avoidance of doubt, a Force Majeure Event does not include (except and to the extent that they result directly from a Force Majeure Event), among others: (i) technical failures, normal wear and tear in machinery, or breakdown in equipment; (ii) shortage of parts, materials or other similar circumstances for which Seller may be responsible pursuant to the Agreement; (iii) late or non-delivery of machinery, equipment, materials or spare parts; (iv) a delay or default in the performance of any Subcontractor or supplier, or any other contractor; (v) strike or labor disturbances limited in scope to those solely affecting Seller or any of its Major Subcontractors; and (vi) changes since the date hereof in applicable Laws or their interpretation.

 

A-76


33.2

Force Majeure Relief

So long as the affected Party has at all times since the occurrence of the Force Majeure Event complied with the obligations of this Clause 33 and continues to so comply, then:

 

  (a)

the affected Party shall not be liable for any failure or delay in performing its obligations which are affected by the Force Majeure Event under or pursuant to the Agreement during the existence of a Force Majeure Event;

 

  (b)

each Party will bear its Cost caused by the circumstances of the Force Majeure Event; and

 

  (c)

in case of a Force Majeure Event affecting Seller, Buyer shall be released from its payment obligations under the Agreement, other than in respect of any amounts that became due and owing under the Agreement prior to the occurrence of the Force Majeure Event that are unpaid, for the duration of the Force Majeure Event.

If Seller claims a Force Majeure Event, Seller shall be entitled to request a Change Order pursuant to Clause 24, in order to obtain an equitable suspension of performance or extension of time (including an extension of the Project Schedule to the extent compliance thereof is affected) with respect thereto.

 

33.3

Notice of Force Majeure

If either Party considers that a Force Majeure Event has occurred which may affect performance of its obligations, it shall notify the other Party as soon as possible but within a maximum of ten (10) Days from the Force Majeure Event occurrence date (or from the date it became aware of the occurrence) giving written particulars of the relevant event and its effect upon its performance under the Agreement and, where known, the expected duration of the failure to perform. If the Party declaring a Force Majeure Event does not notify the other Party within such ten (10) Day period, then any relief provided to the declaring Party under this Clause 33 shall only be available as of the date that such notice was provided to the other Party. As soon as the Force Majeure Event has ended, the Party claiming such Force Majeure Event shall give written notice to the other Party of the precise date of the end of the Force Majeure Event and the extent, with justification, to which it has actually been affected in the performance of its obligations.

 

A-77


33.4

Force Majeure Report

Upon the occurrence of any Force Majeure Event, Seller shall use its best efforts to continue to perform its obligations under the Agreement and to minimize the adverse effects of such Force Majeure Event. Seller shall notify Buyer of the steps it proposes to take including any reasonable alternative means to continue the performance of its obligations under the Agreement. Seller shall not take any such steps unless approved by Buyer. In the case of Seller declaring a Force Majeure Event, within twelve (12) Days after giving such notice Seller shall prepare and deliver to Buyer an appraisal report of the effects of the Force Majeure Event (the “Force Majeure Report”). The Force Majeure Report shall:

 

  (a)

specify the Force Majeure Event;

 

  (b)

describe the damage to and/or other effects on the Liquefaction Train System resulting from the Force Majeure Event; and,

 

  (c)

provide a good faith estimate (in each case to the extent applicable in the circumstances) of:

 

  (i)

the time it will take to restore such condition;

 

  (ii)

the effect which the relevant Force Majeure Event is likely to have upon any other contract relating to the Agreement;

 

  (iii)

whether or not, in Seller’s opinion, the completion or continued manufacturing of the Liquefaction Train System is technically viable with the reasons for such opinion; and

 

  (iv)

include all relevant supporting documentation.

In addition to the Force Majeure Report, Buyer may request, and Seller shall promptly provide, such related information pertaining to the Force Majeure Report as may be reasonable.

 

33.5

Termination for Force Majeure

If circumstances or consequences of a Force Majeure Event have occurred and shall continue for an uninterrupted period of [***] after date of occurrence then, notwithstanding that Seller may by reason thereof have been granted an extension of the Delivery Date, the non-claiming Party shall be entitled to serve upon the Party affected by the Force Majeure Event an additional fifteen (15) Days’ notice to terminate the Agreement. If, at the expiry of such period, the Force Majeure Event is still in effect, the Agreement shall terminate. In the event of a termination of the Agreement due to a Force Majeure Event, the following provisions shall apply:

 

  (a)

neither Party shall have any liability to the other in respect of termination of the Agreement due to a Force Majeure Event, but rights and liabilities which have accrued prior to termination shall survive;

 

A-78


  (b)

upon such termination, Seller shall transfer or assign to Buyer, title in the part of the Liquefaction Train System for which payment has been received in full as of the date of the termination of the Agreement under this Clause 33.5; and

 

  (c)

upon such termination, Buyer shall pay to Seller any unpaid amounts due Seller for Payment Milestones completed as of the date of termination.

 

34.

LIMITED RECOURSE

 

  (a)

Excepting to the extent as otherwise provided in any parent guarantee provided to Seller under the Agreement, in the event of non-performance by Buyer of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (i) any assets or properties of any of the shareholders, members or partners of the Buyer, (ii) any Affiliate of Buyer or (iii) any officers, directors or employees thereof, and no judgment relating to the obligations of Buyer under the Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of Buyer or any other officer, employee or director past, present or future of Buyer or any of its shareholders, members, partners or Affiliates.

 

  (b)

Excepting to the extent otherwise provided in any parent guarantee provided to Buyer under the Agreement, in the event of non-performance by Seller of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (i) any assets or properties of any of the shareholders, members or partners of the Seller, (ii) any Affiliate of Seller or (iii) any officers, directors or employees thereof, and no judgment relating to the obligations of Seller under the Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of the Seller or any other officer, employee or director past, present or future of the Seller or any of its shareholders, members, partners or Affiliates.

 

A-79


APPENDIX B

PRICING; PAYMENT TERMS & CANCELLATION SCHEDULE

See attached.

 

B-1


APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one (1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement; provided that Seller may issue two (2) invoices in November 2021 in connection with LNTP Payment Milestones.

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders.

In addition to the amounts shown in the Payment Milestone in Section I.B., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] during the first [***] of the Payment Schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the Transportation Fixed Fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of $ [***]. In all other cases, Facility-specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Plaquemines Parish sales and use taxes that constitute Buyer Taxes. Any such Plaquemines Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.

 

B-2


I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of LNTP shall be as indicated in the table below.

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   1    [***]    [***]

[***]

   L1    [***]    [***]

[***]

   2    [***]    [***]

[***]

   3A    [***]    [***]

 

B-3


Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   3B    [***]    [***]

[***]

   L2    [***]    [***]

[***]

   4    [***]    [***]

[***]

   4B    [***]    [***]

[***]

   5    [***]    [***]

 

B-4


Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   6    [***]    [***]

 

  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   1    [***]    [***]

[***]

   L1    [***]    [***]

[***]

   2    [***]    [***]

[***]

   3A    [***]    [***]

 

B-5


Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   3B    [***]    [***]

[***]

   L2    [***]    [***]

[***]

   4    [***]    [***]

[***]

   4B    [***]    [***]

[***]

   5    [***]    [***]

[***]

   6    [***]    [***]

[***]

   7    [***]    [***]

[***]

   8    [***]    [***]

[***]

   9    [***]    [***]

[***]

   10    [***]    [***]

[***]

   11    [***]    [***]

[***]

   12    [***]    [***]

 

B-6


Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   13    [***]    [***]

[***]

   14    [***]    [***]

[***]

   15    [***]    [***]

[***]

   16    [***]    [***]

[***]

   17    [***]    [***]

[***]

   18    [***]    [***]

[***]

   19    [***]    [***]

[***]

   20    [***]    [***]

[***]

   21    [***]    [***]

[***]

   22    [***]    [***]

[***]

   23    [***]    [***]

[***]

   24    [***]    [***]

[***]

   25    [***]    [***]

[***]

   26    [***]    [***]

[***]

   27    [***]    [***]

[***]

   28    [***]    [***]

[***]

   29    [***]    [***]

[***]

   30    [***]    [***]

 

B-7


Payment Milestone Notes

1

   [***]

2

   [***]

3

   [***]

4

   [***]

5

   [***]

6

   [***]

7

   [***]

8

   [***]

9

   [***]

10

   [***]

11

   [***]

 

B-8


Payment Milestone Notes

12

   [***]

13

   [***]

14

   [***]

 

B-9


II.

Aggregate Payment Milestone Cap:

The aggregate amount ofall Payment Milestones invoiced by Seller as ofeach month, including all invoices submitted to Buyer in ptior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month. For the avoidance of doubt, the Aggregate Payment Milestone Cap shall be inclusive of the LNTP Advance.

 

  A.

[***]

 

Month after Issuance of LNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

  A.

[***]

 

Month after Issuance of FNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-10


Month after Issuance of FNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-11


Month after Issuance of FNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-12


III.

Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29.1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]

where:

[***]

 

Months after issuance of LNTP or issuance of a Suspension Notice, as
Applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-13


 

3.

If FNTP is issued prior to the tennination of the Agreement, the Maximum Termination Fee shall be as follows; provided, however, that ifFNTP is issued less than [***] after the issuance of LNTP, in either case, the Maximum Termination Fee set forth in the first [***] in the table below shall be increased by [***].

 

Months after issuance of LNTP

or FNTP or issuance of a Suspension

Notice, as applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [ ***]

[***]

   [***]

 

B-14


Months after issuance of LNTP or FNTP

or issuance of a Suspension

Notice, as applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

4.

For the avoidance of doubt, any Te1mination Fee shall be inclusive of the LNTP Advance.

 

 

B-15


APPENDIX C

SCOPE OF SUPPLY & PROJECT SCHEDULE

[Omitted]

 

C-1


APPENDIX D

[INTENTIONALLY OMITTED]

 

D-1


APPENDIX E

QUALITY ASSURANCE AND QUALITY CONTROL

[Omitted]

 

E-1


APPENDIX F

PERFORMANCE TESTS

[Omitted]

 

F-1


APPENDIX G

APPROVED SUBCONTRACTORS

[Omitted]

 

G-1


APPENDIX H

[INTENTIONALLY OMITTED]

 

H-1


APPENDIX I

FORM OF CHANGE ORDER

[Omitted]

 

I-1


APPENDIX J

FORM OF LIEN WAIVERS AND RELEASES

[Omitted]

 

J-1


APPENDIX K

PHYSICAL TRANSPORTATION COSTS

At least six (6) months prior to the delivery of the first Liquefaction Train under the Agreement, Seller shall provide to Buyer for Buyer’s review and approval, such approval not to be unreasonably withheld, conditioned or delayed, a plan for the delivery of the Liquefaction Trains in accordance with the delivery schedule, including the identity of the transportation vendors and the estimated Transportation Costs for the Agreement.

 

K-1


APPENDIX L

LIQUIDATED DAMAGE AMOUNTS

 

I.

Delivery Delay Liquidated Damages (Clause 6.4(c)(i)(1)):

 

Day

  

Liquidated Damage

Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

 

II.

Delivery Delay Liquidated Damages (Clause 6.4(c)(ii)(1)):

 

Day

  

Liquidated Damage

Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]
[***]    $[***]    $[***]

[***]

   $[***]    $[***]

 

L-1


[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

 

III.

Performance Delay Liquidated Damages (Clause 25.3(b)(i)(x)(1)):

 

Day

  

Liquidated Damage

Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

 

L-2


[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

 

IV.

Performance Delay Liquidated Damages (Clause 25.3(b)(i)(y)(1)):

 

Day

  

Liquidated Damage Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

 

L-3


I.

Performance Delay Liquidated Damages (Clause 25.3(b)(ii)(1)):

 

Day

  

Liquidated Damage

Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

[***]

   $[***]    $[***]

 

L-4

Exhibit 10.34

GUARANTY AGREEMENT

THIS GUARANTY AGREEMENT (this “Guaranty”) is made as of the 26th day of February, 2021 by Baker Hughes Holdings LLC, a limited liability company duly organized and existing under the laws of the State of Delaware, with its primary office at 17021 Aldine Westfield Road, Houston, Texas 77073 (herein called “Guarantor”), for the benefit of Venture Global Plaquemines LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware, with its primary office at 1001 19th Street North, Suite 1500, Arlington, VA 22209 (herein called “Buyer”). Guarantor and Buyer are individually referred to herein as a “Party” and collectively as the “Parties.”

RECITALS:

WHEREAS, Baker Hughes Energy Services LLC, a limited liability company organized and existing under the laws of the State of Delaware, with a place of business at 17021 Aldine Westfield Road, Houston, Texas 77073 (herein called “Seller”) is an affiliate of Guarantor;

WHEREAS, Buyer and Seller have entered into a Purchase Order Contract for the Sale of Liquefaction Train System with Seller dated as of February 26, 2021 (together with the schedules, annexes, and exhibits thereto and as the same may be amended from time to time, herein called the “Contract”), for the supply of certain natural gas liquefaction equipment by Seller;

WHEREAS, the Contract requires Guarantor to guarantee Seller’s performance under the Contract for the benefit of Buyer; and

WHEREAS, Guarantor indirectly owns the majority of the membership interests of Seller and, as ultimate parent company of Seller, is willing to enter into this Guaranty in satisfaction of the conditions of the Contract.

NOW, THEREFORE, in consideration of the premises and mutual covenants set forth herein, the Parties hereto agree as follows:

1. Subject to Section 2, Guarantor unconditionally, absolutely and irrevocably guarantees to Buyer, and its successors and assigns, as and for its own obligation, and not as a surety, that in the event of Seller failing in any respect to perform or observe any obligation owed by Seller to Buyer, whether now existing or hereafter arising, under the terms and provisions of the Contract, Guarantor shall within ten (10) Working Days (as such term is defined in the Contract) upon first demand in writing by Buyer (a) perform or take such steps as are necessary to achieve performance or observance of such obligations and (b) shall indemnify, defend and hold harmless the Buyer Parties (as such term is defined in the Contract) against any and all losses, damages, claims, costs, charges, and expenses, howsoever arising, from the said failure to the extent of Seller’s liability under the Contract.

2. Notwithstanding anything to the contrary contained in this Guaranty or the Contract, the Guarantor’s aggregate liability under this Guaranty at any time prior to the issuance of FNTP shall not exceed the applicable Maximum Termination Fee.

 

1


3. This Guaranty constitutes an independent guaranty, and is not conditioned on or contingent upon or modified, impaired or prejudiced by: (a) any attempt to enforce in whole or in part any obligations of Seller to Buyer; (b) the existence or continuance of Seller as a legal entity; (c) the consolidation or merger of Seller with or into any other entity; (d) the sale, lease or disposition by Seller of all or substantially all of its assets to any other entity; (e) the bankruptcy or insolvency of Seller or the making by Seller of a general assignment for the benefit of creditors; (f) any other security now or hereafter held by Buyer as security for the obligations of Seller; (g) the compromise, settlement, release, waiver, change, modification, or termination of any of Seller’s obligations under the Contract; (h) the extension of time for payment of any amounts due from Seller or of the time for performance of any of Seller’s obligations under the Contract; or (i) the failure, omission, delay or lack on the part of Buyer to enforce or exercise any right, power or remedy under or pursuant to the terms of the Contract or this Guaranty.

4. Guarantor’s payment and performance shall be subject to the defenses and the limits on Seller’s liability under the Contract. Guarantor agrees to make any payment due hereunder upon first written demand, without set-off or counterclaim and without any legal formality, such as protest or notice being necessary, and waives all privileges or rights which it may have as a guarantor, including (a) any right to require Buyer to claim payment or to exhaust remedies against Seller or any other person, (b) notice of any fact which might substantially increase Buyer’s risk; (c) notice of presentment for payment, demand or protest and notice thereof as to any instrument; (d) notice of Seller’s default; (e) any defense arising by reason of any incapacity, lack of authority or disability; (f) any defense arising because of the exercise of any right or remedy available to, or election made by, Buyer pursuant to the U.S. Bankruptcy Code and (g) all other notices and demands to which Guarantor might otherwise be entitled.

5. The obligations of Guarantor hereunder are primary and original obligations and shall continue in full force and effect after expiry or termination of the Contract until all of Seller’s obligations and liabilities under the Contract have been fully discharged, without regard to future changes in conditions, including change in law or any invalidity or irregularity with respect to the execution and delivery of this Guaranty.

6. Guarantor irrevocably and absolutely waives any and all rights of subrogation, contribution, indemnification, reimbursement or similar rights against Seller with respect to this Guaranty. In addition, Guarantor will not exercise any rights which it may acquire by way of subrogation under this Guaranty by any payment made hereunder or otherwise, until all of Seller’s obligations owed to Buyer shall have indefeasibly been performed or paid in full.

7. This Guaranty shall continue to be effective or be reinstated, as the case may be, if at any time any payment by Guarantor or Seller to Buyer is annulled, set aside, invalidated, declared to be fraudulent or preferential, rescinded or must otherwise be returned, refunded or repaid by Buyer upon the insolvency, bankruptcy, reorganization, dissolution or liquidation of Seller, Guarantor or otherwise, and is so rescinded or returned to the party or parties making such payment, all as though such payment had not been made.

 

2


8. This Guaranty and the undertakings herein contained shall be binding upon the successors and assigns of Guarantor and shall extend to and inure for the benefit of the successors or permitted assignees of Buyer. Guarantor may not assign its rights and obligations hereunder or assign or otherwise transfer this Guaranty or any interest herein, without the prior written consent of Buyer. Buyer may assign or transfer all or any of its right, title and interest in this Guaranty in connection with any assignment of the Contract in accordance with the requirements specified therein, including a collateral assignment to Lenders (as such term is defined in the Contract). No person other than Buyer or such permitted assignees or transferees as described above is intended as a beneficiary of this Guaranty nor shall any such person have any rights hereunder. 

9. No assignment or transfer of the Contract or this Guaranty shall operate to extinguish or diminish the liability of Guarantor hereunder.

10. This Guaranty shall terminate and shall no longer be of any force or effect, and shall promptly be returned by Buyer to Guarantor, upon the earlier to occur of (a) the performance by Seller of all of its obligations under the Contract or (b) the delivery by Seller of replacement credit support pursuant to and in accordance with the Contract.

11. In the event there is any dispute under the Contract that relates to a sum being claimed under this Guaranty, which dispute is submitted to arbitration in accordance with the Contract, the obligations under this Guaranty with respect to such sum being claimed shall be suspended pending the outcome of such arbitration and Guarantor further agrees that any award resulting from such arbitration shall be conclusive and binding on it for purposes of determining its obligation under this Guaranty.

12. Guarantor represents and warrants to Buyer that: (a) Guarantor is a limited liability company duly formed, validly existing and in good standing under the laws of its jurisdiction of formation; (b) the execution, delivery and performance by Guarantor of this Guaranty have been duly authorized by all necessary actions on the part of Guarantor; and (c) this Guaranty constitutes a legally binding obligation of Guarantor, except as the enforceability hereof may be limited by applicable bankruptcy, insolvency, moratorium and other laws affecting Buyer’s rights generally and by equitable principles (regardless of whether enforcement is sought in equity or at law).

13. Subject to Section 2, Guarantor agrees to pay all expenses (including court costs and reasonable attorney’s fees) incurred by Buyer in connection with defending and enforcing its rights under this Guaranty.

14. This Guaranty shall be governed by and construed in accordance with the laws of the State of New York, excluding only those provisions regarding conflict of laws.

15. The Parties irrevocably waive any objections, which they may have now or hereafter to (a) the personal or subject matter jurisdiction of the federal or state courts located in the State of New York, (b) the venue of any proceedings brought in the federal or state courts located in the State of New York, or (c) that such proceedings have been brought in a non-convenient forum. The Parties irrevocably agree that any final judgment (after appeal or expiration of time for appeal) entered by any such courts shall be conclusive and binding upon the Parties and may be enforced in the courts or any other jurisdiction to the fullest extent permitted by applicable law.

[Signature page follows]

 

3


IN WITNESS WHEREOF, the Parties hereto have caused this Guaranty to be executed by their respective authorized representatives as of the date first written above.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC     BAKER HUGHES HOLDINGS LLC
By:  

/s/ Keith Larson

    By:  

/s/ Lee Whitley

Name:  

Keith Larson

    Name:  

Lee Whitley

Title:

 

Secretary

   

Title:

 

Vice President and Corporate Secretary

 

4

Exhibit 10.35

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

CHANGE ORDER NO. 02

UNDER THE AMENDED AND RESTATED PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

February 25, 2022

Reference is made to the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January 19, 2022 (as amended, the “Agreement”), by and between Venture Global Plaquemines LNG, LLC, a Delaware limited liability company (“Buyer”) and Baker Hughes Energy Services LLC, a Delaware limited liability company (“Seller”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, including any adjustment to the Contract Price and/or the Project Schedule set forth herein, as applicable, has been agreed upon by the Parties in accordance with Clause 24 of Appendix A (General Terms & Conditions) of the Agreement, and is considered an amendment to the Agreement. Except to the extent as may be specifically described in this Change Order, the changes set forth herein do not relieve Seller of any of its responsibilities described in the Agreement.

Once this Change Order is executed by both Parties, and except to the extent set forth herein, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Seller fully for all such effects.

SCOPE:

This change order modifies Appendix A (General Terms & Conditions) of the Agreement, as follows:

Clause 6.7 of Appendix A (General Terms & Conditions) of the Agreement is hereby deleted the in its entirety and the following is inserted in its place:

“6.7 Delivery Bonus

“If Seller delivers a Liquefaction Train to Buyer at the Delivery Point (i) in respect of the first [***] Liquefaction Trains on or before the date that is [***] prior to the relevant Delivery Date for such Liquefaction Train in the Project Schedule, then Buyer shall pay to Seller an amount equal to [***] for each such Liquefaction Train delivered to the Delivery Point prior to the Delivery Date provided for such Liquefaction Train, and (ii) in respect of the subsequent [***] Liquefaction Trains on or before the date that is [***], then Buyer shall pay to Seller an amount equal to [***] for each such Liquefaction Train delivered to the Delivery Point prior to the Delivery Date provided for such Liquefaction Train, each of which amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement; provided, that in no event shall the total aggregate amount of all bonus amounts paid by Buyer under this Clause 6.7 exceed [***]. For the purposes of this


Execution Version

 

Clause 6.7 only, Seller shall be deemed to have delivered any Liquefaction Train described in this Clause 6.7 that is delivered to Buyer at the Delivery Point on or before the date that is at least [***] (with respect to the first [***] Liquefaction Trains) or [***] (in respect of the subsequent [***] Liquefaction Trains), as applicable, in each case prior to the relevant Delivery Date for such Liquefaction Train in the Project Schedule notwithstanding that certain minor items forming a part of the Liquefaction Train have not been delivered to Buyer at the Delivery Point by such date; provided that (i) the Lender’s Engineer has confirmed to Buyer in writing (upon Buyer’s request) that the absence of such minor items would not reasonably be expected to adversely impact the project schedule for testing, commissioning, safety or operability of such Liquefaction Train and (ii) all such minor items are delivered to Buyer at the Delivery Point not later than the relevant Delivery Date for such Liquefaction Train in the Project Schedule or such other date as mutually agreed by the Parties in writing. Amounts earned by Seller pursuant to this Clause 6.7 shall be due and payable by Buyer to Seller upon the completion of delivery by Seller of all Components (as such term is defined in the PIS Purchase Order) of the power island system in accordance with the PIS Purchase Order.”

CONTRACT PRICE

This Change Order has no impact on the Contract Price.

Attached as Exhibit A to this Change Order is a revised version of Appendix B (Pricing; Payment Terms & Cancellation Schedule), which supersedes and replaces the existing Appendix B (Pricing; Payment Terms & Cancellation Schedule) in its entirety.

PROJECT SCHEDULE:

This Change Order has no impact on the Project Schedule or the Milestone Dates.

Notwithstanding anything to the contrary contained herein, this Change Order shall not be construed as the FNTP under Clause 6.6 of Appendix A (General Terms & Conditions) of the Agreement.

Seller waives any and all rights to claim any payment or any relief for time for the performance of its obligations for the performance of the scope of the changes that are set forth under this Change Order. This Change Order constitutes compensation in full for Seller for all delays to the Project Schedule related thereto, and for performance of the changes within the time stated. Notwithstanding, such adjusted Contract Prices does not include any Buyer Taxes which will be added to such Contract Price in accordance with and subject to the terms of the Agreement.

All other terms and conditions of the Agreement remain unchanged and in effect unless specifically modified herein.

[Signature Page Follows.]


Agreed pursuant to the Agreement by:

 

Baker Hughes Energy Services LLC

   

Venture Global Plaquemines LNG, LLC

By:  

/s/ Marco Caccavale

    By:  

/s/ Keith Larson

Name:

  Marco Caccavale    

Name:

  Keith Larson

Title:

  Vice President, TPS Sales    

Title:

  Secretary


Exhibit A

[See attached.]


Execution Version

APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one (1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement; provided that Seller may issue two (2) invoices in November 2021 in connection with LNTP Payment Milestones.

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders.

In addition to the amounts shown in the Payment Milestone in Section I.B., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] during the first [***] of the Payment Schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the Transportation Fixed Fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of [***]. In all other cases, Facility-specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Plaquemines Parish sales and use taxes that constitute Buyer Taxes. Any such Plaquemines Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.


Execution Version

 

I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of LNTP shall be as indicated in the table below.

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   1    [***]    [***]

[***]

   L1    [***]    [***]

[***]

   2    [***]    [***]


Execution Version

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   3A    [***]    [***]

[***]

   3B    [***]    [***]

[***]

   L2    [***]    [***]


Execution Version

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   4    [***]    [***]

[***]

   4B    [***]    [***]

[***]

   5    [***]    [***]

[***]

   6    [***]    [***]

 

  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   1    [***]    [***]

[***]

   L1    [***]    [***]

[***]

   2    [***]    [***]

[***]

   3A    [***]    [***]

[***]

   3B    [***]    [***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   L2    [***]    [***]

[***]

   4    [***]    [***]

[***]

   4B    [***]    [***]

[***]

   5    [***]    [***]

[***]

   6    [***]    [***]

[***]

   7    [***]    [***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   7A    [***]    [***]

[***]

   8    [***]    [***]

[***]

   9    [***]    [***]

[***]

   10    [***]    [***]

[***]

   11    [***]    [***]

[***]

   12    [***]    [***]

[***]

   13    [***]    [***]

[***]

   14    [***]    [***]

[***]

   15    [***]    [***]

[***]

   16    [***]    [***]

[***]

   17    [***]    [***]

[***]

   18    [***]    [***]

[***]

   19    [***]    [***]

[***]

   20    [***]    [***]

[***]

   21    [***]    [***]

[***]

   22    [***]    [***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   23    [***]    [***]

[***]

   24    [***]    [***]

[***]

   25    [***]    [***]

[***]

   26    [***]    [***]

[***]

   27    [***]    [***]

[***]

   28    [***]    [***]

[***]

   29    [***]    [***]

[***]

   30    [***]    [***]

 

Payment Milestone Notes

1

   [***]

2

   [***]

3

   [***]

4

   [***]

5

   [***]


Execution Version

 

Payment Milestone Notes

6

   [***]

7

   [***]

8

   [***]

9

   [***]

10

   [***]

11

   [***]


Execution Version

 

Payment Milestone Notes

12

   [***]

13

   [***]

14

   [***]


Execution Version

 

II.

Aggregate Payment Milestone Cap:

The aggregate amount of all Payment Milestones invoiced by Seller as of each month, including all invoices submitted to Buyer in prior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month. For the avoidance of doubt, the Aggregate Payment Milestone Cap shall be inclusive of the LNTP Advance.

 

  A.

[***]

 

Month after Issuance of LNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

  B.

[***]

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution Version

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution Version

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution Version

 

III.

Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29.1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]

where:

[***]

 

Months after issuance of LNTP or
issuance of a Suspension Notice, as
Applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution Version

 

3.

If FNTP is issued prior to the termination of the Agreement, the Maximum Termination Fee shall be as follows; provided, however, that if FNTP is issued less than [***] after the issuance of LNTP, in either case, the Maximum Termination Fee set forth in the first [***] in the table below shall be increased by [***].

 

Months after issuance of LNTP or
FNTP or issuance of a Suspension
Notice, as applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution Version

 

Months after issuance of LNTP or
FNTP or issuance of a Suspension
Notice, as applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

4.

For the avoidance of doubt, any Termination Fee shall be inclusive of the LNTP Advance.

Exhibit 10.36

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

CHANGE ORDER NO. 03

UNDER THE AMENDED AND RESTATED PURCHASE ORDER CONTRACT.

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

October 24, 2022

Reference is made to the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January 19, 2022 (as amended, the “Agreement”), by and between Venture Global Plaquemines LNG, LLC, a Delaware limited liability company (“Buyer”) and Baker Hughes Energy Services LLC, a Delaware limited liability company (“Seller”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, including any adjustment to the Contract Price and/or the Project Schedule set forth herein, as applicable, has been agreed upon by the Parties in accordance with Clause 24 of Appendix A (General Terms & Conditions) of the Agreement, and is considered an amendment to the Agreement. Except to the extent as may be specifically described in this Change Order, the changes set forth herein do not relieve Seller of any of its responsibilities described in the Agreement.

Once this Change Order is executed by both Parties, and except to the extent set forth herein, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Seller fully for all such effects.

SCOPE:

This Change Order modifies the Payment Milestones. Attached as Exhibit A to this Change Order is a revised version of Appendix B (Pricing; Payment Terms & Cancellation Schedule), which supersedes and replaces the existing Appendix B (Pricing; Payment Terms & Cancellation Schedule) in its entirety.

This Change Order also modifies Appendix C (Scope of Supply & Project Schedule) as set forth below:

 

1.

Section 1.4 (Control System Scope) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by deleting the ninth bullet point in the subsection entitled, “Fire Suppression and Piping Insulation is included as follows:” in its entirety and inserting the following bullet point in its place:

[***]


Execution Version

 

2.

Section 1.3 (Electrical System Scope) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet point immediately after the last bullet point of the section:

[***]

 

3.

Section 1.2.2 (Mixed Refrigerant) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet points immediately after the last sentence of the section:

[***]


Execution Version

 

4.

Section 1.2.2 (Mixed Refrigerant) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet points immediately after the last bullet point in the subsection entitled, “Lube Oil System”:

[***]

 

5.

Section 1.2.2 (Mixed Refrigerant) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last bullet point in the subsection entitled, “Air-Cooled Heat Exchangers (mounted on Modules)”:

[***]

 

6.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last sentence in the subsection entitled, “Fin Fan Air Cooler for VFD (one set for each Liquefaction Block)”:

[***]


Execution Version

 

7.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last sentence in the subsection entitled, “Others”:

[***]

 

8.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last sentence in the subsection entitled, “Utilities”:

[***]


Execution Version

 

CONTRACT PRICE:   

The original Contract Price was:

   $ [***]  

The net adjustment to the Contract Price by previously executed Change Orders is:

   $ [***]  

The Contract Price prior to this Change Order was:

   $ [***]  

The Contract Price shall be increased by this Change Order in the amount (the “Change Order Price”) of:

   $ [***]  

(comprised of: (1) a negative fixed lump sum amount of [***]; with respect to the change set forth in clause 1 above (PCO #63 Rev. 00); (2) a fixed lump sum amount of [***] with respect to the change set forth in clause (2) above (PCO# 87 Rev. 00); (3) a fixed lump sum amount of [***] with respect to the change set forth in clause 3 above (PCOs #69 Rev. 00 [***] and #78 Rev. 03 [***], respectively); (4) a negative fixed lump sum amount of [***] with respect to the change set forth in clause 4 above (PCO #64 [***] and a negative fixed lump sum amount of [***]) with respect to the change set forth in clause 4 (PCO #65 Rev. 02) respectively; (5) a fixed lump sum amount of [***] with respect to the change set forth in clause 5 above (PCO #83 Rev. 01); (6) a fixed lump sum amount of [***] with respect to the change set forth in clause 6 above (PCO #66 Rev. 01); (7) a fixed lump sum amount of [***] with respect to the changes set forth in clause 7 above (PCO #67 Rev. 02 [***] and #68 Rev. 02 [***], and (8) a fixed lump sum amount of [***] with respect to the changes set forth in clause 8 above (PCO #75 Rev. 01)):

  
The adjusted Contract Price, including this Change Order, shall be:    $ [***]  

The original fixed fee for transportation was:

   $ [***]  


Execution Version

 

The net adjustment to the fixed fee by previously executed Change Orders is:

   $ [***]  

The fixed fee prior to this Change Order was:

   $ [***]  

The fixed fee shall be increased by this Change Order in the amount of:

   $ [***]  

The adjusted fixed fee for transportation, including this Change Order, shall be:

   $ [***]  

The original not to exceed amount for Transportation Costs was:

   $ [***]  

The net adjustment to the not to exceed amount for Transportation Costs

   $ [***]  

by previously executed Change Orders is:

  

The adjusted not to exceed amount for Transportation Costs prior to this change order was:

   $ [***]  

The not to exceed amount for Transportation Costs shall be increased by this Change Order in the amount of:

   $ [***]  

The adjusted not to exceed amount for Transportation Costs, including this Change Order, shall be:

   $ [***]  

Exhibit B to this Change Order contains Seller’s cost details for the scope of supply modifications set forth herein for information purposes only.

PROJECT SCHEDULE:

This Change Order has no impact on the Project Schedule or the Milestone Dates.

TERMS AND CONDITIONS:

Buyer and Seller further agree to the following changes to the Agreement:

 

  a.

Clause 6.4(c) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to”[***] Dollars ($[***])“ in its entirety and inserting “[***] Dollars ($[***])” in its place, and (ii) deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.


Execution Version

 

  b.

Clause 25.3(a)(i) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.

 

  c.

Clause 25.3(a)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to”[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])“ in its place.

 

  d.

Clause 25.3(b)(i) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to”[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place, and (ii) deleting the reference therein to”[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.

 

  e.

Clause 25.3(b)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting”[***] Dollars ($[***])” in its place.

Seller waives any and all rights to claim any payment or any relief for time for the performance of its obligations for the performance of the scope of the changes that are set forth under this Change Order. This Change Order constitutes compensation in full for Seller for all costs and expenses directly or indirectly attributable to the changes set forth herein, for all delays related thereto, and for performance of the changes within the time stated. Notwithstanding, such adjusted Contract Price does not include any Buyer Taxes which will be added to such Contract Price in accordance with and subject to the terms of the Agreement.

All other terms and conditions of the Agreement remain in effect unless specifically modified herein.

[Signature Page Follows.]


Agreed pursuant to the Agreement by:

 

Baker Hughes Energy Services LLC

    Venture Global Plaquemines LNG, LLC
By:  

/s/ Jeffrey Hoke

    By:  

/s/ Keith Larson

Name:   Jeffrey Hoke     Name:   Keith Larson
Title:   Project Director     Title:   Secretary


Exhibit A

APPENDIX B

PRICING. PAYMENT TERMS & CANCELLATION SCHEDULE

[See attached.]


Execution Version

 

APPENDIX B

PRICING. PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one (1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement; provided that Seller may issue two (2) invoices in November 2021 in connection with LNTP Payment Milestones.

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders.

In addition to the amounts shown in the Payment Milestone in Section I.B., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] dollars ($[***]) as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] dollars($[***]) during the first [***] of the Payment Schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the Transportation Fixed Fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of $[***]. In all other cases, Facility-specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Plaquemines Parish sales and use taxes that constitute Buyer Taxes. Any such Plaquemines Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.


Execution Version

 

I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of LNTP shall be as indicated in the table below.

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   1    [***]    [***]

[***]

   L1    [***]    [***]

[***]

   2    [***]    [***]


Execution Version

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   3A    [***]    [***]

[***]

   3B    [***]    [***]

[***]

   L2    [***]    [***]


Execution Version

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]    4    [***]    [***]
[***]    4B    [***]    [***]
[***]    5    [***]    [***]
[***]    6    [***]    [***]

 

  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]    1    [***]    [***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]    L1    [***]    [***]
[***]    2    [***]    [***]
[***]    3A    [***]    [***]
[***]    3B    [***]    [***]
[***]    L2    [***]    [***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]    4    [***]    [***]
[***]    4B    [***]    [***]
[***]    5    [***]    [***]
[***]    6    [***]    [***]
[***]    7    [***]    [***]
[***]    7A    [***]    [***]
[***]    8    [***]    [***]
[***]    9    [***]    [***]
[***]    10    [***]    [***]
[***]    11    [***]    [***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]    12    [***]    [***]
[***]    13    [***]    [***]
[***]    14    [***]    [***]
[***]    15    [***]    [***]
[***]    16    [***]    [***]
[***]    17    [***]    [***]
[***]    18    [***]    [***]
[***]    19    [***]    [***]
[***]    20    [***]    [***]
[***]    21    [***]    [***]
[***]    22    [***]    [***]
[***]    23    [***]    [***]
[***]    24    [***]    [***]
[***]    25    [***]    [***]
[***]    26    [***]    [***]
[***]    27    [***]    [***]
[***]    28    [***]    [***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]    29    [***]    [***]
[***]    30    [***]    [***]
[***]    31    [***]    [***]
[***]    32    [***]    [***]
[***]    33    [***]    [***]
[***]    34    [***]    [***]

 

Payment Milestone Notes

1

   [***]

2

   [***]

3

   [***]

4

   [***]

5

   [***]

6

   [***]

7

   [***]


Execution Version

 

Payment Milestone Notes

8

   [***]

9

   [***]

10

   [***]

11

   [***]


Execution Version

 

Payment Milestone Notes

12

   [***]

13

   [***]

14

   [***]

 


Execution Version

 

II.

Aggregate Payment Milestone Cap:

The aggregate amount of all Payment Milestones invoiced by Seller as of each month, including all invoices submitted to Buyer in prior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month. For the avoidance of doubt, the Aggregate Payment Milestone Cap shall be inclusive of the LNTP Advance.

 

  A.

[***]

 

Month after Issuance of LNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

  B

[***]

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution Version

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution Version

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution Version

 

III.

Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29.1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]

where:

[***]

 

Months after issuance of LNTP or

issuance of a Suspension Notice, as

Applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution Version

 

3.

If FNTP is issued prior to the termination of the Agreement, the Maximum Termination Fee shall be as follows; provided, however, that if FNTP is issued less than [***] after the issuance of LNTP, in either case, the Maximum Termination Fee set forth in the first [***] in the table below shall be increased by [***].

 

Months after issuance of LNTP or

FNTP or issuance of a Suspension

Notice, as applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution Version

 

Months after issuance of LNTP or

FNTP or issuance of a Suspension

Notice, as applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

4.

For the avoidance of doubt, any Termination Fee shall be inclusive of the LNTP Advance.


Execution Version

 

Exhibit B

Cost Details

[Omitted]

Exhibit 10.37

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

CHANGE ORDER NO. 04

UNDER THE AMENDED AND RESTATED PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

April 7, 2023

Reference is made to the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January 19, 2022 (as amended, the “Agreement”), by and between Venture Global Plaquemines LNG, LLC, a Delaware limited liability company (“Buyer”) and Baker Hughes Energy Services LLC, a Delaware limited liability company (“Seller”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. Except to the extent as may be specifically described in this Change Order, the changes set forth herein do not relieve Seller of any of its responsibilities described in the Agreement.

Once this Change Order is executed by both Parties, and except to the extent set forth herein, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Seller fully for all such effects.

Buyer and Seller agree to the following changes to the Agreement:

EARLY DELIVERY BONUS

 

  1.

The following defined terms shall be inserted in Clause 1.1 of Appendix A to the Agreement in alphabetical order:

““Bonus Date” has the meaning given to it in Clause 6.7.

Bonus Degradation Factor” has the meaning given to it in Clause 6.7.

E-House” means the building in common between two (2) Liquefaction Trains containing the necessary electrical and control panels to operate the system.” “Super Bonus Date” has the meaning given to it in Clause 6.7.

Super Bonus Degradation Factor” has the meaning given to it in Clause 6.7.”

 

  2.

Appendix A to the Agreement is hereby amended by deleting Clause 6.7 in its entirety and inserting the following in its place:

“6.7 Delivery Bonus

If Seller delivers a Liquefaction Train to Buyer at the Delivery Point, and its associated E-House is ready for shipment at the fabrication site located in [***], in each case on or before the applicable bonus date set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (each, a “Bonus Date”) for such Liquefaction Train and associated E-House, then Buyer


Execution Version

 

shall pay to Seller the applicable bonus amount set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) for such Liquefaction Train and associated E-House. If Seller delivers a Liquefaction Train, and its associated E-House is ready for shipment at Seller’s Subcontractor fabrication site located in [***], before the applicable Delivery Date but after the applicable Bonus Date, the amount payable to Seller in respect of such Liquefaction Train and associated E-House shall be reduced by an amount equal to the applicable bonus degradation factor set forth Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (in each case, the “Bonus Degradation Factor”) multiplied by the number of days from the Bonus Date to the average of the actual date of delivery of such Liquefaction Train to the Delivery Point and the actual date of readiness for shipment of such associated E-House at Seller’s Subcontractor fabrication site located in [***]. Each of such bonus amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement.

In addition to any bonus due pursuant to the preceding paragraph, if Seller delivers a Liquefaction Train to Buyer at the Delivery Point, and its associated E-House is ready for shipment at Seller’s Subcontractor fabrication site located in [***], in each case on or before the applicable super bonus date set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (each, a “Super Bonus Date”) for such Liquefaction Train and associated E-House, then Buyer shall pay to Seller the applicable super bonus amount set forth in Annex C-1 of Appendix C (Scope of Supply

& Project Schedule) for such Liquefaction Train and associated E-House. If Seller delivers a Liquefaction Train, and its associated E-House is ready for shipment at Seller’s Subcontractor fabrication site located in [***], before the applicable Delivery Date but after the applicable Super Bonus Date, the amount payable to Seller in respect of such Liquefaction Train and associated E-House shall be reduced by an amount equal to the applicable super bonus degradation factor set forth Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (in each case, the “Super Bonus Degradation Factor”) multiplied by the number of days from the Super Bonus Date to the later of the actual date of delivery of such Liquefaction Train to the Delivery Point or the actual date of readiness for shipment of the E-House at Seller’s Subcontractor fabrication site located in [***]. Each of such super bonus amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement.

If any of the Liquefaction Trains or associated E-Houses is not delivered to the Delivery Point in its entirety on or before the applicable Delivery Date, then no bonus amount shall be earned or due.

For the purposes of this Clause 6.7 only, Seller shall be deemed to have delivered any Liquefaction Train, or have its associated E-House ready for shipment, as described in this Clause 6.7, on or before the Bonus Date and/or the Super Bonus Date, as applicable, notwithstanding that certain minor items forming a part of such Liquefaction Train or associated E-House have not been delivered to Buyer at the Delivery Point by such Bonus Date or Super Bonus Date; provided that (i) the Lender’s Engineer has confirmed to Buyer in writing (upon Buyer’s request) that the absence of such minor items would not reasonably be expected to adversely impact the project schedule for testing, commissioning, safety or operability of such Liquefaction Train or E-House and (ii) all such minor items are delivered to Buyer at the Delivery Point not later than the relevant Delivery Date for such Liquefaction Train or E-House in the Project Schedule or such other date as mutually agreed by the Parties in writing.


Execution Version

 

Amounts earned by Seller pursuant to this Clause 6.7 shall be due and payable by Buyer to Seller upon completion of delivery by Seller of the Liquefaction Train System and all Components (as such term is defined in the PIS Purchase Order) of the power island system in accordance with the PIS Purchase Order and the finalization of a Change Order within [***] days thereof.”

PROJECT SCHEDULE

Attached as Exhibit A to this Change Order is a revised version of Annex C-1 (Project Schedule) of Appendix C (Scope of Supply & Project Schedule), which supersedes and replaces the existing Annex C-1 (Project Schedule) in its entirety.

CONTRACT PRICE

This Change Order has no impact on the Contract Price.

All other terms and conditions of the Agreement remain unchanged and in effect unless specifically modified herein.

Seller waives any and all rights to claim any payment or any relief for time for the performance of its obligations for the performance of the scope of the changes that are set forth under this Change Order. This Change Order constitutes compensation in full for Seller for all costs and expenses directly or indirectly attributable to the changes set forth herein, for all delays related thereto, and for performance of the changes within the time stated. Notwithstanding, such adjusted Contract Price does not include any Buyer Taxes which will be added to such Contract Price in accordance with and subject to the terms of the Agreement.

All other terms and conditions of the Agreement remain in effect unless specifically modified herein.

[Signature Page Follows.]


Agreed pursuant to the Agreement by:

     
Baker Hughes Energy Services LLC     Venture Global Plaquemines LNG, LLC
By:  

/s/ Marco Caccavale

    By:  

/s/ Keith Larson

Name:   Marco Caccavale     Name:   Keith Larson
Title:   President     Title:   Secretary


Execution Version

 

Exhibit A

Annex C-1

LTS Project Schedule

[Omitted]

Exhibit 10.38

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

CHANGE ORDER NO. 05

UNDER THE AMENDED AND RESTATED PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

May 18, 2023

Reference is made to the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January 19, 2022 (as amended, the “Agreement”), by and between Venture Global Plaquemines LNG, LLC, a Delaware limited liability company (“Buyer”) and Baker Hughes Energy Services LLC, a Delaware limited liability company (“Seller”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, including any adjustment to the Contract Price and/or the Project Schedule set forth herein, as applicable, has been agreed upon by the Parties in accordance with Clause 24 of Appendix A (General Terms & Conditions) of the Agreement, and is considered an amendment to the Agreement. Except to the extent as may be specifically described in this Change Order, the changes set forth herein do not relieve Seller of any of its responsibilities described in the Agreement.

Once this Change Order is executed by both Parties, and except to the extent set forth herein, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Seller fully for all such effects.

SCOPE:

This Change Order modifies the Payment Milestones. Attached as Exhibit A to this Change Order is a revised version of Appendix B (Pricing; Payment Terms & Cancellation Schedule), which supersedes and replaces the existing Appendix B (Pricing; Payment Terms & Cancellation Schedule) in its entirety.

This Change Order also modifies Appendix C (Scope of Supply & Project Schedule) as set forth below:

 

1.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet point immediately after the last bullet point of the subsection “Others”:

[***]


Execution Version

 

2.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting two new bullet points immediately after the last sentence in the subsection titled “Instrumentation & Control”:

[***]

 

3.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting two new bullet points immediately after the last sentence in the subsection titled, “Structures and accessories”:

[***]


Execution Version

 

4.

Section 1.10 (Equipment and Components Preservation) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following immediately after the last paragraph:

[***]


Execution Version

 

5.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following bullet points immediately after the last paragraph:

[***]


Execution Version

 

6.

Hand-Off-Auto Switch credit

Seller shall provide a credit of [***] the Local Hand-Off-Auto Switches for each of the Process Air Cooler electric motors included in the original cost buildup of the Plaquemines Phase 1 Liquefaction Train System PO.

Seller shall change the Liquefaction Train numbering system to reflect the preferred arrival and setting sequence at Site. Seller shall revise approximately [***] project documents along with the purchasing specifications of all impacted tagged equipment to change Liquefaction Train numbering and tagging ensuring consistent numbering and tagging of all equipment.

 

7.

Appendix A to the Agreement is hereby amended by deleting Clause 6.7 in its entirety and inserting the following in its place:

“6.7 Delivery Bonus

If Seller delivers a Liquefaction Train to Buyer at the Delivery Point, and its associated E-House is ready for shipment at the fabrication site located in [***], in each case on or before the applicable bonus date set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (each, a “Bonus Date”) for such Liquefaction Train and associated E-House, then Buyer shall pay to Seller the applicable bonus amount set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) for such Liquefaction Train and associated E-House. If Seller delivers a Liquefaction Train, and its associated E-House is ready for shipment at Seller’s Subcontractor fabrication site located in [***] before the applicable Delivery Date but after the applicable Bonus Date, the amount payable to Seller in respect of such Liquefaction Train and associated E-House shall be reduced by an amount equal to the applicable bonus degradation factor set forth Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (in each case, the “Bonus Degradation Factor”) multiplied by the number of days after the Bonus Date to the average of the actual date of delivery of such Liquefaction Train to the Delivery Point and the actual date of readiness for shipment of such associated E-House at Seller’s Subcontractor fabrication site located in [***]. Each of such bonus amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement. In addition to any bonus due pursuant to the preceding paragraph, if Seller delivers a Liquefaction Train to Buyer at the Delivery Point, and its associated E-House is ready for shipment at Seller’s Subcontractor fabrication site located in [***], in each case on or before the applicable super bonus date set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (each, a “Super Bonus Date”) for such Liquefaction Train and associated E-House, then Buyer shall pay to Seller the applicable super bonus amount set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) for such Liquefaction Train and associated E-House. If Seller delivers a Liquefaction Train, and its associated E-House is ready for shipment at Seller’s Subcontractor fabrication site located in [***], before the applicable Delivery Date but after the applicable


Execution Version

 

Super Bonus Date, the amount payable to Seller in respect of such Liquefaction Train and associated E-House shall be reduced by an amount equal to the applicable super bonus degradation factor set forth Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (in each case, the “Super Bonus Degradation Factor”) multiplied by the number of days after the Super Bonus Date to the average of the actual date of delivery of such Liquefaction Train to the Delivery Point and the actual date of readiness for shipment of such associated E-House at Seller’s Subcontractor fabrication site located in [***]. Each of such super bonus amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement.

If any of the Liquefaction Trains or associated E-Houses is not delivered to the Delivery Point in its entirety on or before the applicable Delivery Date, then no bonus amount shall be earned or due.

For the purposes of this Clause 6.7 only, Seller shall be deemed to have delivered any Liquefaction Train, or have its associated E-House ready for shipment, as described in this Clause 6.7, on or before the Bonus Date and/or the Super Bonus Date, as applicable, notwithstanding that certain minor items forming a part of such Liquefaction Train or associated E-House have not been delivered to Buyer at the Delivery Point by such Bonus Date or Super Bonus Date; provided that (i) the Lender’s Engineer has confirmed to Buyer in writing (upon Buyer’s request) that the absence of such minor items would not reasonably be expected to adversely impact the project schedule for testing, commissioning, safety or operability of such Liquefaction Train or E-House and (ii) all such minor items are delivered to Buyer at the Delivery Point not later than the relevant Delivery Date for such Liquefaction Train or E-House in the Project Schedule or such other date as mutually agreed by the Parties in writing.

Amounts earned by Seller pursuant to this Clause 6.7 shall be due and payable by Buyer to Seller upon completion of delivery by Seller of the Liquefaction Train System and all Components (as such term is defined in the PIS Purchase Order) of the power island system in accordance with the PIS Purchase Order and the finalization of a Change Order within [***] thereof.”

 

CONTRACT PRICE:   
The original Contract Price was:    $[***]
The net adjustment to the Contract Price by previously executed Change Orders is:    $[***]
The Contract Price prior to this Change Order was:    $[***]
The Contract Price shall be increased by this Change Order in the amount (the “Change Order Price”) of:    $[***]


Execution Version

 

(comprised of: (1) a fixed lump sum amount of [***], with respect to the change set forth in clause 1 above (PCO#81 Rev.01); (2) a fixed lump sum amount of [***] with respect to the change set forth in clause 2 above (PCO#82 Rev 03); (3) a fixed lump sum amount of [***] with respect to the change set forth in clause 3 above (PCO# 77 Rev.01); (4) a fixed lump sum in the amount of [***] with respect to the change set forth in clause 3 above (PCO#91 Rev 01); (5) a fixed lump sum amount of [***] with respect to the change set forth in clause 4 above (PCOs #88 Rev. 01); (6) a fixed lump sum amount of [***] with respect to the change set forth in clause 5 above (PCO #89 Rev 0); (7) a fixed lump sum amount of [***] with respect to the change set forth in clause 5 above (PCO#90 Rev 0); (8) a fixed lump sum amount of [***] with respect to the change set forth in clause 5 above (PCO#92 Rev 0); (9) a fixed lump sum amount of [***] with respect to the change set forth in clause 5 above (PCO#94 Rev 0); (10) a credit amount of [***] with respect to the change set forth in clause 5 above (PCO#95 Rev 0); (11) a credit amount of [***] with respect to the change set forth in clause 6 above; and (12) a fixed lump sum amount of [***] with respect to the change set forth in clause 6 above (PCO#99).   
The adjusted Contract Price, including this Change Order, shall be:    $[***]
The original fixed fee for transportation was:    $[***]
The net adjustment to the fixed fee by previously executed Change Orders is:    $[***]
The fixed fee prior to this Change Order was:    $[***]
The fixed fee shall be increased by this Change Order in the amount of:    $[***]
The adjusted fixed fee for transportation, including this Change Order, shall be:    $[***]
The original not to exceed amount for Transportation Costs was:    $[***]


Execution Version

 

The net adjustment to the not to exceed amount for Transportation Costs by previously executed Change Orders is:    $[***]
The adjusted not to exceed amount for Transportation Costs prior to this change order was:    $[***]
The not to exceed amount for Transportation Costs shall be increased by this Change Order in the amount of:    $[***]
The adjusted not to exceed amount for Transportation Costs, including this Change Order, shall be:    $[***]

Exhibit B to this Change Order contains Seller’s cost details for the scope of supply modifications set forth herein for information purposes only.

PROJECT SCHEDULE:

This Change Order has no impact on the Project Schedule or the Milestone Dates.

TERMS AND CONDITIONS:

Buyer and Seller further agree to the following changes to the Agreement:

 

  a.

Clause 6.4(c) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place, and (ii) deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.

 

  b.

Clause 25.3(a)(i) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.

 

  c.

Clause 25.3(a)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] ($[***])” in its place.


Execution Version

 

  d.

Clause 25.3(b)(i) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place, and (ii) deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.

 

  e.

Clause 25.3(b)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.

Seller waives any and all rights to claim any payment or any relief for time for the performance of its obligations for the performance of the scope of the changes that are set forth under this Change Order. This Change Order constitutes compensation in full for Seller for all costs and expenses directly or indirectly attributable to the changes set forth herein, for all delays related thereto, and for performance of the changes within the time stated. Notwithstanding, such adjusted Contract Price does not include any Buyer Taxes which will be added to such Contract Price in accordance with and subject to the terms of the Agreement.

All other terms and conditions of the Agreement remain in effect unless specifically modified herein.

[Signature Page Follows.]


Agreed pursuant to the Agreement by:

 

Baker Hughes Energy Services LLC     Venture Global Plaquemines LNG, LLC
By:  

/s/ Chris Coffman

    By:  

/s/ Keith Larson

Name:   Chris Coffman     Name:   Keith Larson
Title:   Vice President     Title:   Secretary


Exhibit A

APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

[See attached.]


Execution Version

 

APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one (1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement; provided that Seller may issue two (2) invoices in November 2021 in connection with LNTP Payment Milestones. 

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders. 

In addition to the amounts shown in the Payment Milestone in Section I.B., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] dollars ($[***]) as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] dollars ($[***]) during the first [***] of the Payment Schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the Transportation Fixed Fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of $[***]. In all other cases, Facility-specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Plaquemines Parish sales and use taxes that constitute Buyer Taxes. Any such Plaquemines Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.


Execution Version

 

I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of LNTP shall be as indicated in the table below.

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   1    [***]    $[***]

[***]

   L1    [***]    $[***]

[***]

   2    [***]    $[***]


Execution Version

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   3A    [***]    $[***]

[***]

   3B    [***]    $[***]

[***]

   L2    [***]    $[***]


Execution Version

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   4    [***]    $[***]

[***]

   4B    [***]    $[***]

[***]

   5    [***]    $[***]

[***]

   6    [***]    $[***]

 

  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]    1    [***]    $[***]
[***]    L1    [***]    $[***]
[***]    2    [***]    $[***]
[***]    3A    [***]    $[***]
[***]    3B    [***]    $[***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]    L2    [***]    $[***]
[***]    4    [***]    $[***]
[***]    4B    [***]    $[***]
[***]    5    [***]    $[***]
[***]    6    [***]    $[***]
[***]    7    [***]    $[***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]    7A    [***]    $[***]
[***]    8    [***]    $[***]
[***]    9    [***]    $[***]
[***]    10    [***]    $[***]
[***]    11    [***]    $[***]
[***]    12    [***]    $[***]
[***]    13    [***]    $[***]
[***]    14    [***]    $[***]
[***]    15    [***]    $[***]
[***]    16    [***]    $[***]
[***]    17    [***]    $[***]
[***]    18    [***]    $[***]
[***]    19    [***]    $[***]
[***]    20    [***]    $[***]
[***]    21    [***]    $[***]
[***]    22    [***]    $[***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]    23    [***]    $[***]
[***]    24    [***]    $[***]
[***]    25    [***]    $[***]
[***]    26    [***]    $[***]
[***]    27    [***]    $[***]
[***]    28    [***]    $[***]
[***]    29    [***]    $[***]
[***]    30    [***]    $[***]
[***]    31    [***]    $[***]
[***]    32    [***]    $[***]
[***]    33    [***]    $[***]
[***]    34    [***]    $[***]
[***]    35    [***]    $[***]
[***]    36    [***]    $[***]
[***]    37    [***]    $[***]
[***]    38    [***]    $[***]


Execution Version

 

Payment Milestone Notes

1

   [***]

2

   [***]

3

   [***]

4

   [***]

5

   [***]

6

   [***]

7

   [***]

8

   [***]


Execution Version

 

Payment Milestone Notes

9

   [***]

10

   [***]

11

   [***]


Execution Version

 

Payment Milestone Notes

12

   [***]

13

   [***]

14

   [***]

 

II.

Aggregate Payment Milestone Cap:

The aggregate amount of all Payment Milestones invoiced by Seller as of each month, including all invoices submitted to Buyer in prior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month. For the avoidance of doubt, the Aggregate Payment Milestone Cap shall be inclusive of the LNTP Advance. 

 

  A.

[***]

 

Month after Issuance of LNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]


Execution Version

 

B. [***]

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month) after CO#5

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]


Execution Version

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month) after CO#5

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

 

III.

Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29.1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]


Execution Version

 

where:

[***]

 

Months after issuance of LNTP or

issuance of a Suspension Notice, as

Applicable

  

Maximum Termination Fee after CO#5

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

 

3.

If FNTP is issued prior to the termination of the Agreement, the Maximum Termination Fee shall be as follows; provided, however, that if FNTP is issued less than [***] after the issuance of LNTP, in either case, the Maximum Termination Fee set forth in the first [***] in the table below shall be increased by [***].


Execution Version

 

Months after issuance of LNTP

or FNTP or issuance of a

Suspension Notice, as applicable

  

Maximum Termination Fee

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

 

4.

For the avoidance of doubt, any Termination Fee shall be inclusive of the LNTP Advance.


Execution Version

 

Exhibit B

Cost Details

[Omitted]

Exhibit 10.39

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

(Execution version)

CHANGE ORDER NO. 06

UNDER THE AMENDED AND RESTATED PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

December 29, 2023

Reference is made to the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January 19, 2022 (as amended, the “Agreement”), by and between Venture Global Plaquemines LNG, LLC, a Delaware limited liability company (“Buyer”) and Baker Hughes Energy Services LLC, a Delaware limited liability company (“Seller”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, including any adjustment to the Contract Price and/or the Project Schedule set forth herein, as applicable, has been agreed upon by the Parties in accordance with Clause 24 of Appendix A (General Terms & Conditions) of the Agreement, and is considered an amendment to the Agreement. Except to the extent as may be specifically described in this Change Order, the changes set forth herein do not relieve Seller of any of its responsibilities described in the Agreement.

In accordance with Clause 13.3 of Appendix A (General Terms & Conditions), Buyer is hereby specifying in writing (via this Change Order) the Spare Parts that it wishes to purchase and the time when such items should be delivered to a location designated by Buyer.

Once this Change Order is executed by both Parties, and except to the extent set forth herein, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the changes described herein, and shall be deemed to compensate Seller fully for all such effects.

TERMS AND CONDITIONS:

 

1)

Clause 13.3 of the Agreement shall be deleted in its entirety and the following Clause 13.3 shall be inserted in its place:

13.3 Spare Parts

Seller shall sell and deliver, and Buyer shall purchase and accept, spare parts for operating and maintaining the Liquefaction Train System (including components and systems of each such Liquefaction Train System) (“Spare Parts”) in accordance with Annex C-43 of Appendix C (Scope of Supply & Project Schedule). Seller shall ensure that contracts between Seller and Subcontractors for the supply of such Spare Parts to Buyer contain terms and conditions that are appropriate and sufficient to fulfill Seller’s obligations under the Agreement. Notwithstanding the foregoing, Seller and Buyer agree: (1) to waive the requirements set forth in Clause 4.3(b)(iii), (iv), (v), (vi), (vii), (viii) and (x); (2) that, with respect to those requirements set forth in Clause 4.3(b) that are not so waived, Seller shall be deemed to have satisfied such requirements so long as contracts between Seller and Approved Subcontractors for the supply of Spare Parts contain terms and conditions that are materially consistent with such requirements; and (3) the Delivery Delay Liquidated Damage provisions set forth in Clause 6.4 and the Early Delivery Bonus provisions set forth in Clause 6.7 shall not be applicable to the Spare Parts.


(Execution version)

 

2)

Seller and Buyer agree that the first sentence of Clause 6.2 of Appendix A (General Terms & Conditions) shall be deleted in its entirety and the following shall be inserted in its place:

“Seller shall cause each Liquefaction Train or Liquefaction Train System to be delivered on or before the Delivery Date for such Liquefaction Train or Liquefaction Train System; provided that the Spare Parts set forth in Annex C-43 to Appendix C (Scope of Supply & Project Schedule) shall be delivered no later than the applicable dates set forth therein.”

 

3)

Buyer and Seller further agree to the following changes to the Agreement:

 

  a.

Clause 6.4(c) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place, and (ii) deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.

 

  b.

Clause 25.3(a)(i) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.

 

  c.

Clause 25.3(a)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.

 

  d.

Clause 25.3(b)(i) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place, and (ii) deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.

 

  e.

Clause 25.3(b)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***] Dollars ($[***])” in its entirety and inserting “[***] Dollars ($[***])” in its place.

 

2


(Execution version)

 

4)

Seller and Buyer agree that the second sentence of Clause 17.1(a) of Appendix A (General Terms & Conditions) shall be deleted in its entirety and the following two sentences shall be inserted in its place:

“Except as set forth in Clause 17.2, the “Warranty Period” for the warranties in this Clause 17.1 shall be the period starting on the date of Substantial Completion of the Liquefaction Train for the first Liquefaction Train and ending upon: (i) in respect of the first [***] Liquefaction Trains set forth in the Project Schedule, the earlier of (1) [***] after the date of Substantial Completion of the Liquefaction Train System, and (2) [***] from the date that Seller delivered the applicable Liquefaction Train to the Delivery Point, and (ii) in respect of the last [***] Liquefaction Trains set forth in the Project Schedule, the earlier of (1) [***] after the date of Substantial Completion of the Liquefaction Train System and (2) [***] from the date that Seller delivered the applicable Liquefaction Train to the Delivery Point, provided that Buyer and Seller shall enter into the Preservation Agreement, for any Liquefaction Trains that are shipped to storage, if the storage period is for a period greater than [***]. The “Warranty Period” for the warranties in this Clause 17.1 for the Spare Parts set forth in Annex C-43 to Appendix C (Scope of Supply & Project Schedule) shall be, with respect to each such Spare Part, the period starting on the date of delivery of such Spare Part to the Delivery Point and ending upon the earlier of (i) [***] after the date of installation of such Spare Part or (ii) [***] after the date of delivery of such Spare Part to the Delivery Point; provided, that if the storage period for such Spare Parts is greater than [***], Buyer will put in place preservation procedures that are consistent with the Preservation Agreement.”

 

5)

Seller and Buyer agree that Clause 19.2 of Appendix A (General Terms & Conditions) shall be amended by inserting the following sentences immediately following the last sentence of Clause 19.2:

“NOTWITHSTANDING THE FOREGOING, EXCEPT WITH RESPECT TO (A) SELLER’S UNCONDITIONAL PERFORMANCE OBLIGATION, (B) SELLER’S INDEMNITY OBLIGATIONS UNDER CLAUSE 18.8, (C) SELLER’S THIRD PARTY INDEMNITY OBLIGATIONS UNDER CLAUSES 19.1 AND 31.1, PROVIDED THAT EACH OF THE SELLER EXCLUDED PARTIES AND BUYER EXCLUDED PARTIES SHALL NOT BE DEEMED A THIRD PARTY FOR THE PURPOSES OF THIS CLAUSE 19.2, (D) SELLER’S INDEMNITY OBLIGATIONS UNDER CLAUSE 16.5 OR (E) SELLER’S LIABILITY ARISING FROM FRAUD, GROSS NEGLIGENCE, OR WILLFUL MISCONDUCT, SELLER’S AGGREGATE LIABILITY, WHETHER IN CONTRACT, TORT (INCLUDING NEGLIGENCE), STRICT LIABILITY OR OTHERWISE, ARISING OUT OF THE SUPPLY OF THE SPARE PARTS SET FORTH IN ANNEX C-43 TO APPENDIX C (SCOPE OF SUPPLY & PROJECT SCHEDULE), INCLUDING DELAYS OR FAILURE TO DELIVER SUCH SPARE PARTS IN ACCORDANCE WITH THE TERMS HEREIN, OR THE USE OF SUCH SPARE PARTS AFTER THE END OF THE WARRANTY PERIOD, SHALL NOT EXCEED AN AMOUNT EQUAL TO [***].”

 

3


(Execution version)

 

APPENDIX B

Attached as Exhibit A to this Change Order is a revised version of Appendix B (Pricing; Payment Terms & Cancellation Schedule), which supersedes and replaces the existing Appendix B (Pricing; Payment Terms & Cancellation Schedule) in its entirety.

APPENDIX C

Buyer and Seller agree that Appendix C (Scope of Supply & Project Schedule) of the Agreement shall be amended by inserting, immediately following Annex C-42 thereof, the form of Annex C-43 that is attached as Exhibit B to this Change Order.

 

CONTRACT PRICE:

  

The original Contract Price was:

   $ [ ***] 

The net adjustment to the Contract Price by previously executed Change Orders is:

   $ [ ***] 

The Contract Price prior to this Change Order was:

   $ [ ***] 

The Contract Price shall be increased by this Change Order in the amount of:

   $ [ ***] 

(comprised of (1) a fixed lump sum amount of $[***] with respect to the changes set forth in Clause (1) above as further described in Annex C-43 to Appendix C (Scope of Supply & Project Schedule) attached herein)

  

The adjusted Contract Price, including this Change Order, shall be:

   $ [ ***] 

The original fixed fee for transportation was:

   $ [ ***] 

The net adjustment to the fixed fee by previously executed Change Orders is:

   $ [ ***] 

 

4


(Execution version)

 

The fixed fee prior to this Change Order was:

   $ [ ***] 

The fixed fee shall be increased by this Change Order in the amount of:

   $ [ ***] 

The adjusted fixed fee for transportation, including this Change Order, shall be:

   $ [ ***] 

The original not to exceed amount for Transportation Costs was:

   $ [ ***] 

The net adjustment to the not to exceed amount for Transportation Costs by previously executed Change Orders is:

   $ [ ***] 

The adjusted not to exceed amount for Transportation Costs prior to this change order was:

   $ [ ***] 

The not to exceed amount for Transportation Costs shall be increased by this Change Order in the amount of:

   $ [ ***] 

The adjusted not to exceed amount for Transportation Costs, including this Change Order, shall be:

   $ [ ***] 

PROJECT SCHEDULE:

This Change Order has no impact on the Project Schedule or the Milestone Dates.

Seller waives any and all rights to claim any payment or any relief for time for the performance of its obligations for the performance of the scope of the changes that are set forth under this Change Order. This Change Order constitutes compensation in full for Seller for all costs and expenses directly or indirectly attributable to the changes set forth herein, for all delays related thereto, and for performance of the changes within the time stated. Notwithstanding, such adjusted Contract Price does not include any Buyer Taxes which will be added to such Contract Price in accordance with and subject to the terms of the Agreement.

All other terms and conditions of the Agreement remain in effect unless specifically modified herein.

[Signature Page Follows.]

 

5


(Execution version)

 

Agreed pursuant to the Agreement by:      
Baker Hughes Energy Services, LLC     Venture Global Plaquemines LNG, LLC
By:  

/s/ Jeff Hoke

    By:  

/s/ Keith Larson

Name:   Jeff Hoke     Name:   Keith Larson
Title:   Project Director     Title:   Secretary

 

6


(Execution version)

 

Exhibit A

APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one (1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement; provided that Seller may issue two (2) invoices in November 2021 in connection with LNTP Payment Milestones.

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders.

In addition to the amounts shown in the Payment Milestone in Section I.B., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] dollars ($[***]) as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] dollars ($[***]) during the first [***] of the Payment Schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the Transportation Fixed Fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of $[***]. In all other cases, Facility- specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Plaquemines Parish sales and use taxes that constitute Buyer Taxes. Any such Plaquemines Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

 

7


(Execution version)

 

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.

 

I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of LNTP shall be as indicated in the table below.

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   1    [***]    $[***]

[***]

   L1    [***]    $[***]

 

8


(Execution version)

 

[***]

   2    [***]    $[***]

[***]

   3A    [***]    $[***]

[***]

   3B    [***]    $[***]

 

9


(Execution version)

 

[***]

   L2    [***]    $[***]
      [***]   

[***]

   4    [***]    $[***]

[***]

   4B    [***]    $[***]

[***]

   5    [***]    $[***]

[***]

   6    [***]    $[***]

 

10


(Execution version)

 

  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   1    [***]    $[***]

[***]

   L1    [***]    $[***]

[***]

   2    [***]    $[***]

[***]

   3A    [***]    $[***]

 

11


(Execution version)

 

[***]

   3B    [***]    $[***]

[***]

   L2    [***]    $[***]

[***]

   4    [***]    $[***]

[***]

   4B    [***]    $[***]

[***]

   5    [***]    $[***]

[***]

   6    [***]    $[***]

 

12


(Execution version)

 

[***]

   7    [***]    $[***]

[***]

   7A    [***]    $[***]

[***]

   8    [***]    $[***]

[***]

   9    [***]    $[***]

[***]

   10    [***]    $[***]

[***]

   11    [***]    $[***]

[***]

   12    [***]    $[***]

[***]

   13    [***]    $[***]

[***]

   14    [***]    $[***]

[***]

   15    [***]    $[***]

[***]

   16    [***]    $[***]

[***]

   17    [***]    $[***]

[***]

   18    [***]    $[***]

[***]

   19    [***]    $[***]

 

13


(Execution version)

 

[***]

   20    [***]    $[***]

[***]

   21    [***]    $[***]

[***]

   22    [***]    $[***]

[***]

   23    [***]    $[***]

[***]

   24    [***]    $[***]

[***]

   25    [***]    $[***]

[***]

   26    [***]    $[***]

[***]

   27    [***]    $[***]

[***]

   28    [***]    $[***]

[***]

   29    [***]    $[***]

[***]

   30    [***]    $[***]

[***]

   31    [***]    $[***]

[***]

   32    [***]    $[***]

[***]

   33    [***]    $[***]

[***]

   34    [***]    $[***]

 

14


(Execution version)

 

[***]

   35    [***]    $[***]

[***]

   36    [***]    $[***]

[***]

   37    [***]    $[***]

[***]

   38    [***]    $[***]

[***]

   39    [***]    $[***]

[***]

   40    [***]    $[***]

[***]

   41    [***]    $[***]

[***]

   42    [***]    $[***]

 

Payment Milestone Notes

1

   [***]

2

   [***]

3

   [***]

 

15


(Execution version)

 

4

   [***]

5

   [***]

6

   [***]

7

   [***]

8

   [***]

9

   [***]

10

   [***]

11

   [***]

 

16


(Execution version)

 

12

   [***]

13

   [***]

14

   [***]

 

II.

Aggregate Payment Milestone Cap:

The aggregate amount of all Payment Milestones invoiced by Seller as of each month, including all invoices submitted to Buyer in prior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month. For the avoidance of doubt, the Aggregate Payment Milestone Cap shall be inclusive of the LNTP Advance.

A. [***]

 

Month after Issuance of LNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   $ [***]

[***]

   $ [***]

[***]

   $ [***]

[***]

   $ [***]

[***]

   $ [***]

B. [***]

 

17


(Execution version)

 

[***]

 

Month after Issuance of LNTP

or FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month) after

CO#6

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

 

18


(Execution version)

 

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

III. Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29.1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]

 

19


(Execution version)

 

where:

[***]

 

Months after issuance of LNTP or

issuance of a Suspension Notice, as Applicable

  

Maximum Termination

Fee after CO#6

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

 

20


(Execution version)

 

3.

If FNTP is issued prior to the termination of the Agreement, the Maximum Termination Fee shall be as follows; provided, however, that if FNTP is issued less than [***] after the issuance of LNTP, in either case, the Maximum Termination Fee set forth in the first [***] in the table below shall be increased by [***].

 

Months after issuance of LNTP or FNTP or

issuance of a Suspension Notice, as

applicable

  

Maximum Termination Fee

after CO#6

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

 

21


(Execution version)

 

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

For the avoidance of doubt, any Termination Fee shall be inclusive of the LNTP Advance.

 

22


Exhibit B

Annex C-43: Spare Parts

[Omitted]

Exhibit 10.40

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

EXECUTION VERSION

PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

THIS PURCHASE ORDER CONTRACT FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM (hereinafter this “Agreement”) is entered into as of August 5, 2022 (the Effective Date”) by and between BAKER HUGHES ENERGY SERVICES LLC, a limited liability company organized and existing under the laws of the State of Delaware, with an address and place of business at 17021 Aldine Westfield Road, Houston, Texas 77073 (hereinafter the “Seller”), and VENTURE GLOBAL PLAQUEMINES LNG, LLC, a limited liability company organized and existing under the laws of the State of Delaware, with an address at 1001 19th Street North, Suite 1500, Arlington, VA 22209 (hereinafter the “Buyer”).

The Buyer and the Seller are referred to herein individually as a “Party” and collectively as the “Parties”.

RECITALS

WHEREAS, Venture Global LNG, Inc. (“VGLNG”), through its subsidiaries, is developing certain LNG export facilities within the United States of America, including the Facility, as defined in Appendix A (General Terms & Conditions);

WHEREAS, Seller designs, engineers, fabricates and manufactures certain natural gas liquefaction equipment in Seller’s affiliated manufacturing facilities;

WHEREAS, Seller sells Liquefaction Train Systems, as defined in Appendix A (General Terms & Conditions);

WHEREAS, Buyer desires to purchase the Liquefaction Train System from Seller for deployment at the Facility, under the terms and conditions set forth herein;

WHEREAS, Buyer and Seller entered into that certain Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January 19, 2022, in relation to the sale of a liquefaction train system described therein to Buyer with respect to the initial phase of the LNG export terminal and liquefaction project to be located at the Site (the “First LTS Purchase Order”);

WHEREAS, Buyer and Seller entered into that certain Purchase Order Contract for the Sale of Power Island System, dated as of February 3, 2022 in relation to the sale of a power island system described therein to Buyer (the “PIS Purchase Order”); and

WHEREAS, Seller is providing, subject to the terms and conditions of this Agreement, an Unconditional Performance Obligation (as defined herein) with production and efficiency standards for the Liquefaction Train System forming part of the process system of the Facility.


NOW, THEREFORE, in consideration of these Recitals, the mutual covenants, promises and agreements contained herein, and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound, the Parties agree as follows:

 

1.

SCOPE OF SUPPLY

Seller agrees to manufacture, sell and deliver the Liquefaction Train System as set forth in Appendix C (Scope of Supply & Project Schedule) to this Agreement.

 

2.

PRICE AND PAYMENT

In consideration of the supply of a Liquefaction Train System as described in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule), the Buyer will pay to the Seller the contract price in the increments and on the payment schedule as specified in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule). Termination and cancellation charges shall be as specified in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule).

 

3.

PERIOD OF PERFORMANCE

Seller shall complete the performance of all of its obligations set forth in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule) in accordance with the activity completion and delivery schedule described in Appendix C (Scope of Supply & Project Schedule) and the terms of this Agreement. The Liquefaction Train System shall be delivered subject to the Incoterms 2010 as described in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule). Buyer shall complete performance of all of its obligations set forth in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule) in accordance with the terms of this Agreement.

 

4.

TERMS AND CONDITIONS

The following terms and conditions are applicable to this Agreement. The Agreement between the Parties shall be comprised of and consists of the following documents (the “Order Documents”), each of which shall be read and construed as an integral part of the Agreement, listed in order of precedence in case of dispute:

 

     1.   

This document;

  2.   

Appendix A:

  

General Terms & Conditions

  3.   

Appendix B:

   Pricing; Payment Terms & Cancellation Schedule
  4.   

Appendix C:

  

Scope of Supply & Project Schedule

  5.   

Appendix D:

  

Form of Buyer Parent Company Guarantee

  6.   

Appendix E:

   Quality Assurance and Quality Control
  7.   

Appendix F:

  

Performance Tests

  8.   

Appendix G:

  

Approved Subcontractors

 

2


     9.   

Appendix H:

  

Form of Seller Parent Company Guarantee

  10.   

Appendix I:

  

Form of Change Order;

  11.   

Appendix J:

  

Form of Lien Waivers and Releases;

         J-1    Seller Form of Partial Lien Waiver and Release;
         J-2    Seller Form of Final Lien Waiver and Release;
         J-3    Subcontractor Form of Partial Lien Waiver and Release;
         J-4    Subcontractor Form of Final Lien Waiver and Release;
  12.   

Appendix K:

  

Transportation Costs; and

  13.   

Appendix L:

  

Liquidated Damage Amounts.

  14.   

Appendix M:

  

Contract Price Adjustments

 

5.

LIMITED RECOURSE

Excepting to the extent as otherwise provided in any parent guarantee provided to Seller under this Agreement, in the event of non-performance by Buyer of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (a) any assets or properties of any of the shareholders, members or partners of the Buyer, (b) any Affiliate of Buyer or ( c) any officers, directors or employees thereof, and no judgment relating to the obligations of Buyer under this Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of Buyer or any other officer, employee or director past, present or future of the Buyer or any of its shareholders, members, partners or Affiliates. Excepting to the extent as otherwise provided in any parent guarantee provided to Buyer under this Agreement, in the event of non-performance by Seller of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (a) any assets or properties of any of the shareholders, members or partners of the Seller, (b) any Affiliate of Seller or ( c) any officers, directors or employees thereof, and no judgment relating to the obligations of Seller under this Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of the Seller or any other officer, employee or director past, present or future of the Seller or any of its shareholders, members, partners or Affiliates.

 

6.

ENTIRE AGREEMENT

The Order Documents making up the Agreement, excluding for the avoidance of doubt that certain Second Amended and Restated Letter of Agreement, dated as of February 26, 2021, by and between Seller and VGLNG, as amended by Amendment No. 1 to Second Amended and Restated Letter of Agreement dated as of January 19, 2022, Amendment No. 2 to Second Amended and Restated Letter of Agreement dated as of June 23, 2022, Amendment No. 3 to Second Amended and Restated Letter of Agreement dated as of July 6, 2022, Amendment No. 4 to Second Amended

 

3


and Restated Letter of Agreement dated as of July 21, 2022, and Amendment No. 5 to Second Amended and Restated Letter of Agreement dated as of July 29, 2022 (as further amended, amended and restated, supplemented, or otherwise modified from time to time, the “Letter of Agreement”), constitute and represent the entire agreement between the Parties and supersede in their entirety any and all prior agreements or understandings concerning the subject matter hereof, and no modification, amendment, revision, waiver, or other change shall be binding on either Party unless consented to in writing by the Parties or their authorized representatives. Any oral or written representation, warranty, course of dealing or trade usage not contained or referenced herein shall not be binding on either Party. Each Party agrees that it has not relied on, or been induced by, any representations of the other Party not contained in this Agreement.

 

7.

GOVERNING LAW; DISPUTE RESOLUTION

This Agreement shall be subject to the dispute resolution and governing law provisions as further described in Clause 20 and Clause 21 of Appendix A (General Terms & Conditions).

 

8.

INTERPRETATION

Capitalized terms used in this Agreement that are not otherwise defined shall have the meaning given in Appendix A (General Terms & Conditions) and the rules of interpretation set forth in Clause 1.2 of Appendix A (General Terms & Conditions) shall apply to this Agreement.

[SIGNATURES APPEAR ON THE FOLLOWING PAGE]

 

4


IN WITNESS WHEREOF the Parties have caused this Agreement to be executed by their authorized representatives on the Effective Date.

 

SELLER:    BUYER:
BAKER HUGHES ENERGY SERVICES LLC    VENTURE GLOBAL PLAQUEMINES LNG,LLC
By:   /s/ Marco Caccavale                By:   /s/ Keith Larson            
Name: Marco Caccavale    Name: Keith Larson
Title:  Vice President, TPS Sales    Title:  General Counsel


APPENDIX A

GENERAL TERMS & CONDITIONS

 

1.

DEFINITIONS AND INTERPRETATION

 

1.1

Definitions.

Unless otherwise defined elsewhere in the Agreement, the following terms shall have the following meanmgs:

“Affiliate” with respect to a Party means an entity (including without limitation any individual, corporation, partnership, limited liability company, association or trust) controlling, controlled by or under common control with that Party. As used herein, “control” means the possession, directly or indirectly, of the power to direct or cause the direction of the management of policies of such Party, whether through the ownership of voting securities or other interest, by contract or otherwise. For the avoidance of doubt, for the purposes of this Agreement Venture Global Calcasieu Pass, LLC shall not be deemed to be an Affiliate of Buyer.

“Aggregate Delivery Delay Liquidated Damages Cap” means an amount equal to [***] of the Contract Price.

“Aggregate Performance Delay Liquidated Damages Cap” means an amount equal to [***] of the Contract Price.

Anti-Corruption Laws” has the meaning given to it in Clause 16.5(b ).

Approved Subcontractors” means the Subcontractors listed under “Selected Subcontractors” in Appendix G (Approved Subcontractors) of the Agreement and that are otherwise proposed by Seller and approved by Buyer in accordance with Clause 4.2.

“Background Intellectual Property” means all Intellectual Property, relevant to this Agreement, that a Party created or acquired before February 26, 2021 or that a Party creates or acquires independently of the Agreement and not in the performance of its obligations hereunder.

“Bankruptcy Event” means, with respect to a Person, that such Person: (a) files a petition or otherwise commences, or authorizes the commencement of, a proceeding or cause under any bankruptcy, insolvency, receivership or similar law for the protection of creditors; (b) has such a petition filed or proceeding commenced against it, which remains undismissed for ninety (90) Days; ( c) files an answer or pleading admitting or failing to contest the material allegations of any such petition; (d) takes any action for its winding up, liquidation or dissolution; ( e) is otherwise adjudged bankrupt or insolvent under any bankruptcy, insolvency, receivership or similar law for the protection of creditors; or ( f) consents to any of the actions described in clauses (a) through ( e) of this definition being taken against it.

 

A-1


“BAR Policy” has the meaning given to it in Clause 23.4.

“Basis of Design” has the meaning given to it in Appendix C (Scope of Supply & Project Schedule).

“Benefitted Party” has the meaning given to it in Clause 8.2.

“BR-Transient Liquefaction Train Simulation Model” has the meaning given to it in Clause 18.9.

“Buyer” has the meaning given to it in the preamble of the Agreement.

“Buyer Developed Intellectual Property” has the meaning given to it in Clause 18.4.

“Buyer Excluded Parties” means Buyer, Owner and each of their Affiliates, Venture Global Calcasieu Pass, LLC and all other entities directly or indirectly owned by Venture Global LNG, Inc., and each of their subsidiaries, owners, shareholders and all of their respective directors, officers, assigns and employees, and the EPC Contractor (and EPC Contractor’s respective affiliates, subsidiaries, owners, shareholders and its respective directors, officers, assigns and employees).

“Buyer Inspection Parties” means Buyer, Owner, Owner’s customers, Lenders, Lender’s Engineer and their respective representatives and agents.

“Buyer Parent Company Guarantee” means the guarantee, in the form set out in Appendix D (Form of Buyer Parent Company Guarantee), to be issued by Buyer’s parent company and delivered by Buyer to Seller in accordance with Clause 7.8.

“Buyer Parties” means Buyer, Owner, the Lenders and each of their Affiliates and all of their respective directors, officers, agents, advisors, engineers, contractors, consultants, representatives, assigns, employees and any other Person acting on behalf of any of them or in representation, interest, benefit thereto.

“Buyer Taxes” means any and all existing or future taxes, Duties, fees, or other charges of any nature (including, but not limited to, ad valorem, consumption, excise, franchise, gross receipts, import, export, license, property, sales and use, stamp, storage, transfer, turnover, or value-added taxes, or other similar taxes, and any and all items of deficiency, penalty, addition to tax, interest, or assessment related thereto), imposed by any Governmental Authority of the United States of America ( or any political subdivision thereof) in connection with the execution of the Agreement or the purchase of the Liquefaction Train System, but excluding Seller Taxes.

“Buyer’s Representatives” has the meaning given to it in Clause 22.1.

“Calcasieu Purchase Order” means the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of September 25, 2018, between Seller and Venture Global Calcasieu Pass, LLC.

“Change Order” has the meaning given to it in Clause 24.1.

 

A-2


“Cold Box” means the Liquefaction Train cold box, as further described in Appendix C (Scope of Supply & Project Schedule).

“Confidential Information” has the meaning given to it in Clause 22.1.

“Contract Price” means the aggregate amount stated in Clause 7 .1 for the purchase of the Liquefaction Train System, as further described in Appendix B (Pricing; Payment Terms & Cancellation Schedule) and as such amount may be modified pursuant to a Change Order signed by Seller and Buyer in accordance with the requirements of the Agreement.

Costs” means all reasonable and documented expenses, costs and third party disbursements incurred by a Party, but excluding any such expenses, costs and disbursements that are excluded pursuant to Clause 19.3.

“Country” means the United States of America.

“Credit Rating” means the current (a) rating issued or maintained by S&P or Moody’s with respect to such entity’s long-term senior, unsecured, unsubordinated debt obligations (not supported by third party credit enhancements) or (b) corporate credit rating or long-term issuer rating issued or maintained with respect to such entity by S&P or Moody’s.

Day” means a calendar day, i.e. any twenty-four (24) hour period beginning and ending at 12:00 midnight in the State of Louisiana, unless otherwise specified herein as starting from a specific hour.

“Defect” means a failure to meet any warranty set forth in Clause 17 .1.

“Delay Limit Date” means the date on which Seller has accrued an aggregate amount of Delivery Delay Liquidated Damages in an amount equal to or greater than (a) the applicable Delivery Delay Liquidated Damages Cap, or (b) Aggregate Delivery Delay Liquidated Damages Cap.

“Delivery Delay Event” means each instance in which Seller fails to deliver a Liquefaction Train (in its entirety) or Deliverable, as applicable, by its associated Delivery Date.

“Delivery Delay Liquidated Damages” has the meaning given to it in Clause 6.4(a).

“Delivery Delay Liquidated Damages Cap” means, in respect of each Liquefaction Train, an amount equal to (a) [***] of the Aggregate Delivery Delay Liquidated Damages Cap in respect of each of the first [***] Liquefaction Trains to be delivered, and (b) [***] of the Aggregate Delivery Delay Liquidated Damages Cap in respect of each of the subsequent [***] Liquefaction Trains to be delivered.

 

A-3


“Deliverables” means all information, including the Technical Documentation, that was first conceived, reduced to practice or created by Seller or its employees or Subcontractors in the performance of its obligations under the Agreement, a list of which is set forth in Appendix C (Scope of Supply & Project Schedule).

“Delivery Date” means, for each Liquefaction Train or Deliverable, as applicable, the date on which such Liquefaction Train or Deliverable, as applicable, is required to be delivered by Seller to Buyer (pursuant to the Incoterms of the Agreement) in accordance with the Agreement, as further described in the Project Schedule.

“Delivery Point” has the meaning given to it in Clause 9 .1.

“Disclosing Party” has the meaning given to it in Clause 22.1.

“Dispute” has the meaning given to it in Clause 20.1.

“Dollars” means the lawful currency of the United States of America.

“Duties” has the meaning given to it in Clause 7 .1.

“EAR” has the meaning given to it in Clause 16.2.

“EDR File” has the meaning given to it in Clause 18.6.

“Effective Date” has the meaning given to it in the preamble of the Agreement.

“EPC Agreement” means the agreement that Owner enters into with one or more Persons for the construction of the Facility.

“EPC Contractor” means any Person (other than Owner) that is a party to the EPC Agreement.

“Event of Default” means an event of default of Seller described in Clause 28.1 or an event of default of Buyer described in Clause 28.2, which in each case has not been cured within the applicable cure period, if any, as provided by the terms of such Clauses.

“Facility” means the second phase of the LNG export terminal and liquefaction project to be located at the Site.

“Factory Acceptance Tests” has the meaning given to it in Clause 14.5.

“Finance Agreements” means the agreements entered into or to be entered into between Owner or its Affiliates and the Lenders and the other documents related thereto for the purpose of providing financing, refinancing or other financial services for the Facility.

“Financial Closing” means that all of the conditions precedent set forth in the Finance Agreements shall have been satisfied or waived and the Lenders party thereto have disbursed the initial loans thereunder.

 

A-4


“First LTS Purchase Order” has the meaning given to it in the recitals of the Agreement.

“FNTP” has the meaning given to it in Clause 6.6.

“Force Majeure Event” has the meaning given to it in Clause 33.1.

“Force Majeure Report” has the meaning given to it in Clause 33.4.

“Governmental Authority” means any federal, state, regional, city or local government, any intergovernmental association or political subdivision thereof, or other governmental, regulatory or administrative agency, court, commission, administration, department, board, or other governmental subdivision, legislature, rulemaking board, tribunal or other governmental authority with jurisdiction over Seller, Seller Parties ( as may be applicable), Buyer, Owner, EPC Contractor, the Liquefaction Train System(s) or any part thereof or the Site, or any Person acting as a delegate or agent of any Governmental Authority.

“Government Official” has the meaning given to it in Clause 16.5(c).

“Guaranteed Liquefaction Train Substantial Completion Date” means, with respect to a Liquefaction Train, the last day of the Liquefaction Train Testing Period (as defined in Appendix F (Performance Tests)) for such Liquefaction Train, on which Substantial Completion of the Liquefaction Train for such Liquefaction Train is required to be achieved.

“Guaranteed Liquefaction Train System Substantial Completion Date” means the last day of the Liquefaction Train System Testing Period (as defined in Appendix F (Performance Tests)), on which Substantial Completion of the Liquefaction Train System is required to be achieved.

“Hazardous Materials” means any chemical, substance, material or emission, including H2S gas, that is or may be regulated, governed, listed or controlled pursuant to any international, national, federal, provincial, state or local statute, ordinance, order, directive, regulation, judicial decision or other legal requirement applicable to Site as a toxic substance, hazardous substance, hazardous material, dangerous or hazardous waste, dangerous good, pesticide, radioactive material, regulated substance or any similar classification, or any other chemical, substance, emission or material, including, without limitation, petroleum or petroleum-derived products or by-products, regulated, governed, listed or controlled or as to which liability is imposed on the basis of potential impact to safety, health or the environment pursuant to any rule or regulation promulgated by any Governmental Authority.

“ICC Rules” has the meaning given to it in Clause 20.2.

“Instruments of Service” has the meaning given to it in Clause 18.5.

“Intellectual Property” means all intellectual property and proprietary rights thereto, including all rights of inventorship and authorship, inventions, patents, patent applications, patent disclosures, know-how, processes, methods, machines, manufactures, designs, compositions of matter, or any new or useful improvement thereof, copyrights, copyright registrations and applications for

 

A-5


copyright registration, trademark, trade dress and service mark rights and registrations and applications for registration thereof, and all rights in trade secrets, computer software, data and databases, and mask works, all rights of attribution and integrity and other moral rights and all other intellectual property rights of any type, in each case whether registered or unregistered and including all applications for, and renewals and extensions of such rights and all similar or equivalent rights or forms of protection in any part of the world.

“Intellectual Property Claim” means any claim, demand, suit or legal action arising out of or based on any actual or alleged unauthorized disclosure, use or misappropriation of any Intellectual Property, or, any actual or alleged infringement or other violation of any right in, to or under, any Intellectual Property of any other Person that: (a) concerns any materials, deliverables, Work Product or other services provided by Seller, any of its Affiliates, or any Subcontractor under the Agreement; (b) is based upon or arises out of the performance under the Agreement by Seller, any of its Affiliates, or any Subcontractor, including the use of any tools or other implements of construction by Seller, any of its Affiliates, or any Subcontractor; or (c) is based upon or arises out of Buyer’s exercise of its rights pursuant to and in accordance with Clause 18.

“Key Personnel” means the project director appointed by Seller pursuant to Clause 3, each deputy project director and any other senior supervisory personnel as agreed between the Parties in writing.

“kWh” means kilowatt hour.

“Law” means all constitutions, treaties, laws, statutes, edicts, decrees, ordinances, rules, regulations, tariffs, codes, injunctions, writs, requirements, instructions, order and other legal acts of any Governmental Authority or any body under the control of a Governmental Authority.

“Lender” means (i) any Person that does or proposes to lend money, finance or provide financial support or equity in any form in respect of the Facility and/or the general business and operations of Owner or each of its Affiliates (including any refinancing thereof), including any export credit agency, funding agency, bondholder, insurance agency, underwriter, investor, commercial lender or similar institution, together with any agent or trustee for such Person and (ii) any provider of any hedging arrangement entered into in connection with the arrangements described in clause (i) above, including an interest rate swap transaction or a forward interest rate swap transaction, in each case together with any agent or trustee for such provider.

“Lender’s Engineer” is any Person appointed by the Lenders to represent them on technical matters related to the Facility.

“Letter of Agreement” has the meaning set forth in Section 6 of the Agreement.

“Lien” means any mortgage, deed of trust, pledge, lien, security interest, option agreement, conditional sale agreement, title retention agreement, claim, equity, attachment, covenant, condition or restriction, charge or encumbrance or any agreement of any kind, in or with respect to any real or personal property.

 

A-6


“Liquefaction Train” means the mixed refrigerant compression package, including the Cold Box, surge vessel and other equipment purchased by Buyer from Seller producing approximately [***] MTPA of LNG at design outlet pressure and ambient design conditions of [***] degrees Fahrenheit and [***] relative humidity, at sea level, as further described in Appendix C (Scope of Supply & Project Schedule).

“Liquefaction Train Performance Guarantees “ means the Liquefaction Train Production Capacity Performance Guarantee and the Liquefaction Train Power Demand Performance Guarantee.

“Liquefaction Train Performance Tests” means the Liquefaction Train performance tests described in Appendix F (Performance Tests).

“Liquefaction Train Power Demand Minimum Performance Guarantee” means power demand for a Liquefaction Train of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train Production Capacity Performance Guarantee.

Liquefaction Train Power Demand Performance Guarantee” means power demand for a Liquefaction Train of[***] of LNG produced at design conditions and while satisfying the Liquefaction Train Production Capacity Performance Guarantee.

Liquefaction Train Power Demand Liquidated Damages” has the meaning given to it in Clause 25.3(a).

Liquefaction Train Production Capacity Performance Guarantee” means LNG production capacity of [***] MTPA.

“Liquefaction Train Production Capacity Liquidated Damages” has the meaning given to it in Clause 25.3(b).

“Liquefaction Train System” means the mixed refrigerant compression package, including the Cold Box, surge vessel and other equipment purchased by Buyer from Seller in a configuration of twelve (12) Liquefaction Trains capable of producing an aggregate of approximately [***] MTPA of LNG at design conditions, as further described in Appendix C (Scope of Supply & Project Schedule).

Liquefaction Train System Performance Guarantees” means the Liquefaction Train System Production Capacity Performance Guarantee, the Liquefaction Train System Power Demand Performance Guarantee, the Refrigerant Losses Performance Guarantee and the LNG Quality Performance Guarantee.

“Liquefaction Train System Performance Delay Liquidated Damages Cap” means an amount equal to [***] of the Aggregate Performance Delay Liquidated Damages Cap.

“Liquefaction Train System Performance Tests” means the Liquefaction Train System performance tests described in Appendix F (Performance Tests).

 

A-7


“Liquefaction Train System Power Demand Minimum Performance Guarantee” means power demand for the Liquefaction Train System of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train System Production Capacity Performance Guarantee.

“Liquefaction Train System Power Demand Performance Guarantee” means power demand for the Liquefaction Train System of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train System Production Capacity Performance Guarantee.

“Liquefaction Train System Power Demand Liquidated Damages” has the meaning given to it in Clause 25.3(a).

“Liquefaction Train System Production Capacity Performance Guarantee” means LNG production capacity for the Liquefaction Train System of [***] MTPA and [***] at [***] and [***], without considering the maintenance cycle for the Liquefaction Trains.

“Liquefaction Train System Production Capacity Liquidated Damages” has the meaning given to it in Clause 25.3(b)(ii).

“Liquidated Damages” means Delivery Delay Liquidated Damages, Performance Delay Liquidated Damages and the Performance Liquidated Damages, collectively.

“Liquidated Damages Cap” means an amount equal to [***] of the Contract Price.

“LNG” has the meaning given to it in the Basis of Design.

“LNG Quality Performance Guarantee” means that the LNG composition meets the criteria in Annex C-2 of Appendix C (Scope of Supply & Project Schedule).

“LNG Quality Liquidated Damages” has the meaning given to it in Clause 25.3(b)(ii).

“LNTP” has the meaning given to it in Clause 6.6.

“Losses” means any and all losses, liabilities, damages, costs, charges, expenses, fines, interest, awards, penalties and taxes, which are the result of or arise in connection with any actions, suits, claims, demands, causes of action, litigation, lawsuits, administrative proceedings or administrative investigations.

“Major Component” has the meaning given to it in Clause 4.2.

Major Subcontractor” means any Subcontractor identified in Appendix G having a contract with Seller in relation to Seller’s performance of this Agreement with an aggregate value in excess of One Million Dollars ($1,000,000).

“Maximum Termination Fee” has the meaning given to it in Clause 29.2.

 

A-8


“Milestone” means an event that is identified as a milestone in the Project Schedule.

“Minimum Performance Guarantees” means the Liquefaction Train Power Demand Minimum Performance Guarantee, the Liquefaction Train System Power Demand Minimum Performance Guarantee, and the Refrigerant Losses Performance Guarantee.

“Mixed Refrigerant” means a mixture of gases or liquids, including ethylene, propane, i-pentane, nitrogen and other gases as may be required to operate a Liquefaction Train.

“Module” means the natural gas liquefaction module forming part of a Liquefaction Train, as further described in Appendix C (Scope of Supply & Project Schedule).

“Month” means a calendar month according to the Gregorian Calendar beginning at 12:00 midnight in the State of Louisiana, on the last Day of the preceding month and ending at 12:00 midnight in the State of Louisiana, on the last Day of the current month, unless otherwise specified herein as from another Day to the Day preceding the same Day of following Month.

“Moody’s” means Moody’s Investor Services, Inc. and any successor thereto.

“MTPA” means million Tonnes of LNG per annum.

“Notice of Dispute” has the meaning given to it in Clause 20.1.

“Operation And Maintenance Manuals” means the manuals described as such in Appendix C (Scope of Supply & Project Schedule).

“Other Party” has the meaning given to in Clause 8.2.

“Outside Intellectual Property” has the meaning given to it in Clause 18.6.

“Owner” means Venture Global Plaquemines LNG, LLC and any of its successors and assigns.

Party” or “Parties” has the meaning given to it in the preamble of the Agreement.

“Payment Milestone” means the event or group of events to be achieved in order to entitle Seller to invoice the payment, as listed in Appendix B (Pricing; Payment Terms & Cancellation Schedule).

“Payment Schedule” has the meaning given to it in Clause 7 .1.

“Performance Delay Liquidated Damages” means the Liquefaction Train Production Capacity Liquidated Damages, the Liquefaction Train System Production Capacity Liquidated Damages and the LNG Quality Liquidated Damages.

 

A-9


“Performance Delay Liquidated Damages Cap” means: (a) in respect of each Liquefaction Train, an amount equal to (i) [***] of the Aggregate Performance Delay Liquidated Damages Cap in respect of each of the first [***] Liquefaction Trains to be performance tested and (ii) [***] of the Performance Delay Liquidated Damages Cap in respect of each of the subsequent [***] Liquefaction Trains to be performance tested; and (b) in respect of the Liquefaction Train System Production Capacity Performance Guarantee and the LNG Quality Performance Guarantee, collectively, an amount equal to [***].

“Performance Guarantees” means the Liquefaction Train Performance Guarantees and the Liquefaction Train System Performance Guarantees.

“Performance Liquidated Damages” means the Liquefaction Train Power Demand Liquidated Damages and the Liquefaction Train System Power Demand Liquidated Damages.

“Performance Liquidated Damages Cap” means an amount equal to [***].

“Performance Tests” means the Liquefaction Train Performance Tests and the Liquefaction Train System Performance Tests.

“Person” means any individual, corporation, partnership, joint venture, limited liability company, association, joint stock company, trust, unincorporated organization, entity, government or other political subdivision.

“PIS Purchase Order” has the meaning given to it in the recitals of the Agreement.

“Preservation Agreement” means the agreement that Buyer and Seller may negotiate and enter into pursuant to which (a) some or all of the Liquefaction Trains will be stored in a storage facility meeting Seller’s requirements for [***] or more, up to [***], and (b) Seller will for commercially reasonable market-based rates provide Buyer with preservation and maintenance services for such Liquefaction Trains while such Liquefaction Trains are in stored in the storage facility.

“Project Schedule” means the activity completion and delivery schedule set forth in Appendix C (Scope of Supply & Project Schedule).

“Qualified Financial Institution” means a U.S. commercial bank or a U.S. branch office of a foreign bank having, in either case, (a) assets of at least $10,000,000,000 and (b) a Credit Rating from one or both of S&P and Moody’s, which Credit Rating is at least “A-” from S&P (if such bank has a Credit Rating from S&P) and “A3” from Moody’s (if such bank has a Credit Rating from Moody’s).

Ready for Test” means that the Liquefaction Train or the Liquefaction Train System, as applicable, (i) has been installed and is mechanically complete, (ii) has completed Seller’s commissioning and start-up activities pursuant to the Services Agreement, (iii) is capable of being operated safely in accordance with requirements under the EPC Agreement, and (iv) is ready for the Performance Tests to be performed in accordance with the Agreement.

 

A-10


“Rebatable Louisiana Sales and Use Tax” has the meaning given to it in Clause 8.2.

“Receiving Party” has the meaning given to it in Clause 22.1.

Refrigerant Losses Performance Guarantee“ means the loss in Mixed Refrigerant from compressor seals on one Liquefaction Train of [***] based on a normal back pressure of [***].

Reliability Guarantee” has the meaning given to it in Clause 25.1(g).

Representatives” means (a) in the case of Buyer, Buyer’s Representatives and (b) in the case of Seller, Seller’s Representatives.

“SDN” has the meaning given to it in Clause 16.5(a).

“S&P” means Standard & Poor’s Corporation and any successor thereto.

Seller” means Baker Hughes Energy Services LLC, together with its successors and permitted assigns, who shall sell and deliver the Liquefaction Trains under the Agreement.

Seller Competitors” means [***] or any of their respective Affiliates and any other entities that are competitors of Seller [***], as Buyer and Seller may agree from time to time.

Seller Developed Intellectual Property” has the meaning given to it in Clause 18.3.

“Seller Excluded Parties” means Seller and its Affiliates and all of their respective directors, officers, assigns and employees and Seller’s Approved Subcontractors, and General Electric Company and each of its subsidiaries, owners, shareholders and all of their respective directors, officers, assigns and employees.

Seller Parent Company Guarantee” means the guarantee, in the form set out in Appendix H (Form of Seller Parent Company Guarantee), to be issued by Seller’s Guarantor and delivered by Seller to Buyer in accordance with Clause 7.9.

“Seller’s Guarantor” means Baker Hughes Holdings LLC, a Delaware limited liability company.

“Seller’s Know-How” means all of the information, technique and/or know-how related to the design, engineering, manufacturing, construction, operation, maintenance, optimization, repair and servicing of the Liquefaction Train System which was owned by Seller prior to the Agreement or acquired by Seller during performance of the Agreement.

 

A-11


“Seller Parties” means Seller and its Affiliates and all of their respective directors, officers, agents, advisors, engineers, contractors, consultants, representatives, assigns, employees and any other Person acting on behalf of any of them or in representation, interest, benefit thereto.

“Seller’s Representatives” has the meaning given to it in Clause 22.1.

“Seller Taxes” means any and all existing or future (a) corporate and personal income taxes imposed on Seller and its employees by the applicable Laws of any country and (b) taxes, Duties, fees, or other charges of any nature (including, but not limited to, ad valorem, consumption, excise, franchise, gross receipts, import, export, license, property, sales and use, stamp, storage, transfer, turnover, or value-added taxes, or other similar taxes, and any and all items of deficiency, penalty, addition to tax, interest, or assessment related thereto), imposed by any Governmental Authority of any country, other than the United States of America (or any political subdivision thereof), in connection with the execution of the Agreement, Seller’s sale and delivery of the Liquefaction Trains or Seller’s performance of its other obligations under the Agreement.

“Serial Defect” has the meaning given to it in Clause 17.2(c).

“Services” means all the services to be provided under the attendant and separate Services Agreement.

“Services Agreement” means that certain Field Services Agreement, dated as of May 2, 2022, between Buyer and the Seller for the supply of, among other things, technical field services, training, on-Site advisory services during the installation, start-up, commissioning and testing of the Liquefaction Trains and the oversight of the coming into operation of the Liquefaction Trains prior to the Substantial Completion of the Facility as more fully described therein.

“Services Provider” means Seller or Seller’s Affiliate that provides the Services under the Services Agreement.

“Site” means the site located in Plaquemines Parish, Louisiana, as further described in Appendix C (Scope of Supply & Project Schedule).

“Spare Parts” has the meaning given to it in Clause 13.3.

“Subcontractor” means any Person to whom any part of Seller’s obligations under the Agreement has been subcontracted to by Seller.

“Substantial Completion of the Facility” means “Facility Substantial Completion” as defined in the EPC Agreement.

“Substantial Completion of the Liquefaction Train” means that the Liquefaction Train (i) has achieved Ready for Test, (ii) has completed the Liquefaction Train Performance Tests and (iii) either (1) has satisfied all Liquefaction Train Performance Guarantees or (2) has satisfied the Liquefaction Train Power Demand Minimum Performance Guarantee and Seller has paid all payable liquidated damages for the Liquefaction Train Performance Guarantees that were not met.

 

A-12


“Substantial Completion of the Liquefaction Train System” means that the Liquefaction Train System (i) has achieved Ready for Test, (ii) has completed the Liquefaction Train System Performance Tests and (iii) either (1) has satisfied all Liquefaction Train System Performance Guarantees or (2) has satisfied the Liquefaction Train System Power Demand Minimum Performance Guarantee and the Refrigerant Losses Performance Guarantee and Seller has paid all applicable liquidated damages for the Liquefaction Train System Performance Guarantees that were not met.

“Technical Documentation” means all technical documentation, specifications, samples, patterns, models, calculations, computer programs (software), Operation And Maintenance Manuals and other documents or information of a similar nature, to be submitted by Seller to Buyer in native files, in accordance with Clause 18, and .PDF in accordance with Appendix C (Scope of Supply & Project Schedule). A list of files required to be submitted in native format is set forth in Appendix C (Scope of Supply & Project Schedule).

“Termination Fee” has the meaning given to it in Clause 29.2.

“Tonne” means metric ton and is defined as 2204.6 lbs.

“Transportation Costs” has the meaning given to it in Clause 7.1.

“Unconditional Performance Obligation” means Seller’s absolute obligation to achieve (a) the Liquefaction Train Production Capacity Performance Guarantee for each and every Liquefaction Train, (b) the Liquefaction Train System Production Capacity Performance Guarantee, (c) the LNG Quality Performance Guarantee, (d) the Minimum Performance Guarantees and (e) the Reliability Guarantee.

“VGLNG” has the meaning given to it in the recitals of the Agreement.

“Warranty Period” means the period, specified as such in Clause 17.1.

“Week” means a calendar week consisting of seven (7) Days.

“Working Day” means any Day other than a Saturday, or a Sunday or a legal holiday in the State of New York (solely for the purpose of a payment obligation) or the State of Louisiana (with respect to all other obligations).

“Work Product” has the meaning given to it in Clause 18.1.

 

A-13


1.2

Interpretation

In the Agreement, unless the context otherwise requires or the relevant provision(s) expressly state otherwise:

 

  (a)

the headings to the clauses and the emphasizing are for convenience only and do not affect the interpretation of the Agreement;

 

  (b)

all references to documents or other instruments include all amendments and replacements thereof and supplements thereto;

 

  (c)

all references to any statute or statutory provision shall include references to any statute or statutory provision which amends, extends, consolidates or replaces the same or which has been amended, extended, consolidated or replaced by the same and shall include any orders, regulations, instruments or other subordinate legislation made under the relevant statute;

 

  (d)

reference to a ‘Person’ or ‘Persons’ or a ‘party’ or ‘parties’ includes individuals, bodies corporate, unincorporated associations and partnership and that Person’s or those Persons’ personal representatives, successors and permitted assignees, private or public bodies or individuals;

 

  (e)

any obligation on a Party to do anything shall be deemed to include an obligation to procure such thing to be done; any obligation not to do anything shall be deemed to include an obligation not to permit or not to suffer such thing;

 

  (f)

when a time-limit is determined in Days, it expires at the end of the last Day and it is counted from Day to Day; when it is determined in Months, it is counted from Day of Month to Day of Month; if the last Day of either time-limit is a public holiday, the time-limit is extended to the end of the first Working Day that follows;

 

  (g)

save exceptions agreed to by Buyer, the only measurement units admitted are the internationally used measurement units of the metric system;

 

  (h)

if any reference is made in the Agreement to Incoterms or any standards such as ISO standards, the particular Incoterms or standards will apply only:

 

  (i)

to the particular item in respect of which they are used; and,

 

  (ii)

to the extent that such application is not conflicting with the content of the Agreement;

 

  (i)

‘including’ shall, unless expressly stated otherwise, mean ‘including without limitation’;

 

  (j)

references to a ‘Clause’ shall be to a clause of the Agreement;

 

A-14


  (k)

the singular number includes the plural number and vice versa;

 

  (1)

reference to any gender includes the other;

 

  (m)

‘hereunder,’ ‘hereof,’ ‘hereto’ and words of similar import shall be deemed references to the Agreement as a whole and not to any particular Clause or other provision hereof or thereof;

 

  (n)

the term ‘or’ is not exclusive, regardless of whether ‘and/or’ is used in the applicable provision; and

 

  (o)

if the Buyer assigns the Agreement to the EPC Contractor, all references to “Buyer” hereunder shall be treated as a reference to “EPC Contractor”, and if Buyer does not assign this Agreement to the EPC Contractor, each reference to “Buyer” hereunder shall be treated as a reference to “Owner”.

 

1.3

Communications - Notices

Any notice, instruction, consent, approval, comment, certificate or determination to be given in connection with the Agreement shall be effective only if in writing and addressed to the Person, as each Party or Owner has identified below: (a) on delivery, if delivered personally to the Person; (b) on transmission, if transmitted to the facsimile number of the Person or by electronic mail; and (c) on posting, if by first class or overnight mail (postage prepaid). No change of address for a Party or Owner shall be effective until written notice of the change of address is provided to the other Parties and Owner in accordance with this Clause 1.3.

If to Buyer:

[***]

If to Seller:

[***]

 

A-15


If to Owner: [***]

 

1.4

Language

 

  (a)

All correspondence between Buyer and Seller as well as all Technical Documentation and comments thereto and shipping marks shall be in English.

 

  (b)

The Operation and Maintenance Manuals, all markings on equipment, labels, sign-boards, instrument dials, graphical interfaces with the process control system, safety documentation, machine and component name plates shall be in English.

 

A-16


1.5

No Joint Venture, Partnership or Association

 

  (a)

The Agreement shall not be interpreted or construed to create an association, joint venture, or partnership between the Parties or to impose any partnership obligation or liability upon either Party.

 

  (b)

Neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.

 

1.6

Parties to act reasonably

 

  (a)

Where reference is made in the Agreement to a Party’s decision, approval, refusal, consent, agreement, act, etc., such shall not be taken, given or withheld unreasonably or unfairly, unless otherwise expressly stated.

 

  (b)

In all cases the Party claiming a breach of the Agreement by the other Party, shall be obligated to make commercially reasonable efforts to mitigate its costs, losses or damages that have occurred or that may occur as a result of such breach.

 

2.

REQUESTS AND CLARIFICATIONS

Seller represents and warrants to Buyer that Appendix C (Scope of Supply & Project Schedule) includes all of the necessary obligations that are required to be performed by Seller in order for the Liquefaction Train System to operate in accordance with the requirements of the Agreement and satisfy the design codes, standards and the Performance Guarantees set forth in the Agreement. The Parties acknowledge and agree that Appendix C (Scope of Supply & Project Schedule) describes the items for the Liquefaction Train System being provided in general, but not in complete detail. The Parties agree that any specific items not set forth in Appendix C (Scope of Supply & Project Schedule), or any details or clarifications thereto, that are required in order to satisfy the requirements of the Agreement or to satisfy the design codes, standards and the Performance Guarantees set forth in the Agreement, in each case, will not be considered changes to Appendix C (Scope of Supply & Project Schedule), unless they are explicitly excluded from Appendix C (Scope of Supply & Project Schedule), or are changes to the Basis of Design directed by Buyer, or changes pursuant to the Change Order requirements of Clause 24, and Seller waives any right to adjust the Contract Price or the Project Schedule with respect thereto. The Parties acknowledge and agree that Appendix C (Scope of Supply & Project Schedule) contains certain single-line diagrams, pipe and instrumentation diagrams and other diagrams and drawings that will change as Seller completes its engineering of the Liquefaction Train System and that any change to such diagrams and drawings, which are not the result of changes to the Basis of Design directed by Buyer, or changes pursuant to the Change Order requirements of Clause 24, will not be changes that will entitle either Party to changes in the Contract Price or an extension of the Project Schedule.

 

A-17


Buyer may issue to Seller requests or non-material clarifications that are not inconsistent with the obligations of Seller under Appendix C (Scope of Supply & Project Schedule) which Buyer may consider necessary or helpful to Seller in the performance of Seller’s obligations under the Agreement. Seller will evaluate Buyer’s requests or clarifications within a reasonable time period and provide feedback in writing to Buyer. Seller agrees to cooperate with Buyer’s other contractors, including the EPC Contractor.

In the event any such request or clarification of Buyer is transmitted orally, Seller may require Buyer to confirm such request or clarification in writing. Seller shall notify Buyer of such requirement to confirm in writing without undue delay but in any event within seven (7) Working Days of receipt of Buyer’s verbal transmission. If Seller has requested such written confirmation, the request or clarification shall not be effective until written confirmation thereof has been received by Seller.

Any such request or clarification from Buyer shall not relieve Seller from its responsibility for delivering the Liquefaction Trains and performing its other obligations in accordance with the Agreement.

Seller and Buyer agree to reasonably cooperate and work together in good faith with the shared objective of using the experience, knowledge and data derived from the performance under the Agreement, the First L TS Purchase Order and the Calcasieu Purchase Order to optimize the project management services, engineering services, procurement, manufacturing and performance of the Liquefaction Train System in combination with the balance of plant of the Facility (excluding Seller’s improvements that are unrelated to and do not impact the performance, reliability or maintenance of the Liquefaction Train System) with the common goals of (a) increasing the operational performance of the Liquefaction Train System and (b) if possible and solely to the extent consistent with clause (a), reducing the Contract Price; provided, however, that Seller and Buyer acknowledge that (i) no particular result is assured or guaranteed from such price optimization efforts and (ii) Seller shall not be permitted to change the means and methods of its performance or the Basis of Design: (1) in a manner that would deny or reduce the value to Buyer of the benefits of the optimization of the performance of the Liquefaction Train System achieved by Buyer or (2) except as contemplated under Clause 6.6, without the prior written approval of Buyer. Prior to implementation, Buyer shall consult with Seller in respect of any modifications that adversely and materially impact the inlet, exit or throughput conditions of the Liquefaction Train System. Notwithstanding the foregoing, if and to the extent that Seller makes adjustments to its means and methods or design specifications under the Calcasieu Purchase Order after the Effective Date that relate to Seller achieving the performance guarantees set forth in the Calcasieu Purchase Order, such adjustments may be incorporated into the Agreement.

 

3.

PROJECT DIRECTOR

Seller shall provide all oversight and superintendence that is necessary for the performance of its obligations, and obligations of its personnel and the personnel of its Subcontractors, under the Agreement. Seller shall appoint by no later than the Effective Date a competent and authorized representative who shall act as project director and devote the necessary time to the oversight and superintendence of the same and who shall have the authority to

 

A-18


act on Seller’s behalf under the Agreement and receive, on behalf of Seller, requests or clarifications from Buyer. In addition, to the extent that such persons are still employees of Baker Hughes Company, then Seller shall make available to Buyer for the performance of this Agreement the same senior supervisory personnel that are presently engaged with Venture Global Plaquemines LNG, LLC in respect of the liquefaction trains under the First LTS Purchase Order. The replacement of, or additions to, the Key Personnel shall only be made with persons having qualifications and experience comparable to those being replaced or added to. In connection with any substitution of Key Personnel, Buyer shall (a) include a detailed explanation and reason for the request and the resumes of professional education and experience for a minimum of two (2) candidate(s) of suitable qualifications and experience and (b) discuss such candidates in advance with Buyer in order to allow Buyer to provide feedback and request for clarifications. Seller shall use commercially reasonable efforts to take Buyer’s recommendations into consideration. In addition, Buyer may if it is concerned with the performance of any Key Personnel request the removal of, and Seller shall use commercially reasonable efforts to comply with such request to remove and replace, such Key Personnel; provided that if Buyer reasonably demonstrates that such Key Personnel has: (i) been gravely incompetent or negligent in the performance of his or her duties, or (ii) engaged in activities in material violation of the Law or of any safety and security protocols of Buyer that were communicated to Seller in writing, Seller shall promptly remove such Key Personnel and replace such Key Personnel in accordance with this Clause 3.

 

4.

ASSIGNMENT AND SUBCONTRACTING

 

4.1

Assignment

Buyer shall not transfer or assign the Agreement or any of its rights under or interest in the Agreement (including monies that are due or monies that may be due) without the prior written consent of Seller, which consent shall not be unreasonably withheld, conditioned or delayed; provided, however, that Buyer shall not need the consent of Seller (a) to transfer or assign the Agreement to its Affiliate (to the extent such Affiliate is organized under the laws of the United States of America), (b) to transfer or assign the Agreement to the EPC Contractor subject to the requirements under this Clause 4.1 or (c) to assign, charge or otherwise encumber the Agreement or any rights or benefits arising thereunder or therefrom by way of collateral in favor of Lenders. Seller may only transfer or assign the Agreement or any of its rights under or interest in the Agreement (including monies that are due or monies that may be due) with the prior written consent of Buyer, which consent shall not be unreasonably withheld, conditioned or delayed; provided, however, that Seller shall not need the consent of Buyer to assign or novate the Agreement to any Affiliate of Seller that is ultimately wholly owned by Baker Hughes Company and assign any receivables due Seller hereunder to one (1) or more Affiliates of Seller or to third parties. The Parties agree to execute such documents as may be necessary to effect any permitted assignments or transfers of the Agreement. In connection with any collateral assignment of the Agreement by Buyer, Seller shall provide any customary agreements, certificates, legal opinions or other documents reasonably required by any Lender. In connection with any assignment of the Agreement to the EPC Contractor by Buyer, Seller shall agree to

 

A-19


any modifications to the Agreement that are reasonably requested by the EPC Contractor, so long as such modifications do not impose any additional risk, costs, expenses or liability on Seller or Owner. In the event of a transfer or assignment of the Agreement by (i) Buyer, (A) Buyer’s assignee or transferee shall have financial capabilities, directly or by virtue of credit enhancements or other financial arrangements, that are comparable or better than Buyer’s, as of the Effective Date, and (B) Buyer shall cause the credit support under Clause 7.8 to be maintained or provide Seller with replacement credit support that is reasonably acceptable to Seller and substantially similar as provided to Seller hereunder (in which case, if the conditions of Clause 4.l(i)(A) and (i)(B) are met, any credit support that was provided to Seller prior to such assignment shall be promptly returned by Seller to Buyer) and (ii) Seller, Seller shall cause the credit support under Clause 7 .9 to be maintained or provide Buyer with replacement credit support that is reasonably acceptable to Buyer and substantially similar as provided to Buyer hereunder. Any assignment, novation, transfer or other disposal in violation of this Clause 4.1 shall be null and void ab initio and shall not be binding on the Parties. For any assignment by Buyer of the Agreement either to Affiliates, EPC Contractor or any other third parties, Buyer acknowledges that Seller shall perform its standard “Know Your Customer” due diligence (which involves various compliance and financial due diligence) on the proposed assignee and the proposed assignee must satisfy the “Know Your Customer” requirements.

 

4.2

Subcontracting

Seller and Buyer agree that Seller may not utilize the services of any Subcontractors without obtaining Buyer’s prior written approval, which approval may not be unreasonably delayed or withheld. As of the Effective Date, Buyer has agreed that Seller may, subject to the remaining provisions of this Clause 4.2 and Clause 8.4, utilize the services of the Approved Subcontractors listed in Appendix G (Approved Subcontractors). Seller may only utilize the services of the Approved Subcontractors (a) that satisfy Buyer’s quality requirements and (b) in accordance with the requirements set forth in this Clause 4.2. If Seller is considering utilizing the services of any Subcontractor that is not an Approved Subcontractor, then Seller shall notify Buyer of its proposal for such Subcontractor to become an Approved Subcontractor and furnish to Buyer all information reasonably requested by Buyer with respect to the qualifications of such proposed Subcontractor. Buyer shall have the right, acting reasonably, to reject any such proposed Subcontractor, and Seller shall not enter into any subcontract with such proposed Subcontractor that is rejected by Buyer. If an Approved Subcontractor, that has been selected to provide or is providing equipment, becomes subject to bankruptcy or insolvency proceedings or is unable, in Seller’s reasonable judgment, to supply all of the relevant equipment due to capacity constraints, Seller and Buyer will collaborate to develop a list of three or fewer acceptable Subcontractors to replace or supplement such Approved Subcontractor, and shall amend Appendix G accordingly. If Buyer rejects such proposed Subcontractor and the existing Approved Subcontractors are not acceptable in Seller’s reasonable determination for price, quality or schedule reasons, then Seller shall be entitled to a Change Order for any resulting incremental increase in price or delay in the Delivery Date as a result of Buyer’s rejection of such proposed Subcontractor. Approval of any Subcontractor under this Clause 4.2 shall only be for the portion of Seller’s obligations so approved by Buyer. No subcontract with an Approved Subcontractor shall bind or purport to bind Buyer, but each such subcontract shall contain a provision permitting its assignment to Buyer, Owner or the Lenders upon Buyer’s or Seller’s written request.

 

A-20


Seller acknowledges and agrees that Buyer shall have the right to consent to and approve the supplier of each major component of equipment comprising the Liquefaction Train System, [***] ( each a “Major Component”), and confirms the strategy to use the same Approved Subcontractor identified on Appendix G for each item, as identified by its specific Tag Number, for all Liquefaction Trains. To assist Buyer in the selection of Major Components, for each potential vendor or supplier of a Major Component, Seller agrees to provide Buyer with access to: (a) the identity of the potential vendor or supplier; (b) the delivery and schedule terms for the Major Component; ( c) in the case of the Cold Boxes and heat exchangers, the price negotiated by Seller for such Major Components; and (d) all technical and performance information for each Major Component requested by Buyer. To the extent a Major Component supplier is changed based on a Buyer directive and, as a result of such change in Major Component supplier, Seller incurs a documented incremental increase in the price of the Major Component or delay in the delivery of the Major Component that adversely affects the Delivery Date, Seller shall be entitled to a Change Order for an equitable adjustment in the Contract Price and the Project Schedule for the applicable Liquefaction Train System. To the extent that Seller obtains a discount or reduced purchase price from the supplier of Cold Boxes as referenced against the pricing provided by the supplier of Cold Boxes with respect to the First LTS Purchase Order, Seller agrees to pass such discount or savings on to Buyer through a reduction in the Contract Price, except to the extent such discount or reduced purchase price results from a material change in the terms and conditions between Seller and such supplier of Cold Boxes that is adverse to Seller. No such discount or material change shall result in a reduction in the quality or capability of performance of the Liquefaction Train System.

Seller further acknowledges that it shall notify Buyer before subcontracting with any Major Subcontractor (excluding for the avoidance of doubt any Approved Subcontractor) supplying materials or fabrication services in connection with the performance of this Agreement that is located in Asia. Buyer shall have the right to reject any such Major Subcontractor so long as a reasonably comparable subcontractor located outside of Asia is identified as capable of performing the relevant scope of supply, and in such event Seller shall not enter into a subcontract with the Asia-based entity. If Buyer has rejected such proposed Major Subcontractor and the comparable subcontractor located outside of Asia that was identified as capable of performing the relevant scope of supply is not acceptable, in Seller’s reasonable determination, for price, quality or schedule reasons (with Seller having validated for Buyer its determination as to such comparable subcontractor), then, unless such comparable subcontractor is an Approved Subcontractor, Seller shall be entitled to a Change Order for any resulting incremental and documented increase in the Contract Price or adjustment to the Project Schedule, in each case as a result of Buyer’s rejection of such proposed Major Subcontractor.

 

A-21


4.3

Other

 

  (a)

Seller hereby acknowledges and agrees that the review or acceptance of any contract between Seller and an Approved Subcontractor by Buyer and the acceptance of the Approved Subcontractors shall not: (i) modify or relieve, in any way, the obligations of Seller pursuant to the Agreement; (ii) be raised as a claim or as a defense or counterclaim to any claim in connection with the Agreement; or (iii) constitute any approval or acceptance of the work, services or equipment provided under such subcontract or by such Approved Subcontractor.

 

  (b)

At a minimum, all contracts between Seller and an Approved Subcontractor shall require the following:

 

  (i)

such Approved Subcontractor shall comply with all applicable professional standards, permits and Laws, rules, codes and regulations and with the performance standards of Seller under the Agreement;

 

  (ii)

Buyer and Owner shall have all the inspection rights that Buyer and Owner have under the Agreement;

 

  (iii)

such Approved Subcontractor shall be subject to the applicable labor obligations and the safety and security provisions under the Agreement;

 

  (iv)

such Approved Subcontractor shall provide guarantees and warranties with respect to the work and services performed and the materials provided under such contract;

 

  (v)

such Approved Subcontractor shall (A) obtain and carry the insurance coverages (with limits appropriate to the value of such contract) required of Seller pursuant to Clause 23 from an insurance carrier with an A rating from A.M. Best and naming Buyer as an “additional insured”, and (B) provide certificates of insurance as set forth herein;

 

  (vi)

such contract shall be subject to the dispute resolution procedures as set forth herein;

 

  (vii)

such Major Subcontractor(s) shall provide the applicable Lien waiver and releases required under Clause 7 .6, in connection with each payment to Seller hereunder;

 

  (viii)

such Approved Subcontractor(s) shall grant a license to Buyer m accordance with Clause 18.1 and Clause 18.3;

 

  (ix)

such contract shall be subject to the confidentiality provisions set forth under the Agreement; and

 

  (x)

such contract shall be subject to the anti-corruption provisions set forth in Clause 16.5.

 

A-22


  (c)

All contracts between Seller and an Approved Subcontractor must specify that the contractual relationship with such Approved Subcontractor is exclusive to Seller and that such Approved Subcontractor waives any and all rights to demand any payment directly from Buyer and Owner. All contracts between Seller and Approved Subcontractors shall preserve and protect the rights of Buyer and Owner, shall not prejudice such rights and shall require each Approved Subcontractor to enter into similar agreements with its subcontractors. As between Seller and Buyer, Seller shall be solely responsible for the acts, omissions or defaults of the Approved Subcontractors and their agents, representatives and employees. Nothing in the Agreement shall be construed to impose on Buyer or Owner any obligation, liability or duty to an Approved Subcontractor or any other Subcontractor or to create any contractual relationship between any Subcontractor, including any Approved Subcontractor, or other third party and Buyer, including an obligation to pay or to see to the payment of any moneys due any such Subcontractor, Approved Subcontractor or other third party.

 

  (d)

No Approved Subcontractor is intended to be nor shall be deemed a third party beneficiary of the Agreement. In addition to the requirements set forth above, Seller shall include in each contract with an Approved Subcontractor language under which Buyer and Owner shall be made express third party beneficiaries of such contract. If any Approved Subcontractor or proposed Subcontractor refuses to name Buyer and Owner as a third party beneficiary or provide for a right of assignment to Buyer, then Seller shall not use such Subcontractor for any portion of Seller’s obligations hereunder, unless Buyer’s prior written consent is obtained.

 

  (e)

Contingent upon receipt of Buyer’s designation in writing as set forth below, Seller hereby assigns to Buyer ( and Buyer’s permitted assigns) all its interest in any contracts with Approved Subcontractors ( or any portion thereof to the extent such contracts also relate to other projects of Seller) now existing or hereafter entered into by Seller for performance of any part of the work or services, or provision of any materials under the Agreement. Such assignment of Approved Subcontractor contracts will be effective upon written acceptance by Buyer in writing and only as to those contracts which Buyer designates in such written acceptance.

 

5.

SCOPE

Seller agrees to have the Liquefaction Modules manufactured at Seller’s Affiliate’s manufacturing facilities located in [***], and to sell and deliver the Liquefaction Trains and provide the associated Technical Documentation to Buyer as set forth in Appendix C (Scope of Supply & Project Schedule) by the respective Delivery Dates, all in compliance with all other obligations under the Agreement. If Seller’s planned expansion of the manufacturing facilities located in [***] described in this Clause 5 is not

 

A-23


completed, is suspended or is otherwise delayed as a result of delays and other issues in obtaining any required permits, authorizations, licenses and approvals from Governmental Authorities, Seller shall be entitled to an equitable adjustment to the applicable Delivery Date(s) with respect to the last six (6) Liquefaction Trains set forth in the Project Schedule, but not to exceed [***]

 

6.

COMPLIANCE WITH TIME-LIMITS

 

6.1

Effective Date - Time for delivery

After the Effective Date, Seller shall diligently proceed with the performance of its obligations under the Agreement in accordance with the Project Schedule and the other requirements of the Agreement.

 

6.2

Progress of Works - Delay

Seller shall cause each Liquefaction Train to be delivered on or before the Delivery Date for such Liquefaction Train. If, at any time, Seller’s actual progress with respect to a Liquefaction Train is not consistent with meeting the Delivery Date for such Liquefaction Train, or as from the moment any of Seller’s personnel working on the Liquefaction Train System becomes aware of the fact that a Milestone for a Liquefaction Train cannot be met that will affect the Delivery Date for a Liquefaction Train, Seller shall promptly provide written notice to Buyer of such occurrence and shall develop, a recovery plan to overcome the anticipated delay and provide to Buyer, within ten (10) Working Days of such occurrence, a report identifying:

 

  (a)

the likely period of delay;

 

  (b)

the event causing the delay;

 

  (c)

the impact which such event has had or in the opinion of Seller is likely to have or will have on its ability to achieve any of the Milestones;

 

  (d)

the recovery plan developed by Seller to overcome the anticipated delay and the steps which Seller has taken, is taking and will take to mitigate the adverse consequences of such event; and

 

  (e)

further particulars of the consequences of the delay as Seller becomes aware.

Seller shall, in consultation with Buyer, implement the recovery plan and use best efforts to minimize or remove the actual or anticipated delay and any consequences thereof. If Buyer provides notice to Seller that Buyer reasonably believes that the steps proposed by Seller fail to adequately address the anticipated delay in meeting the Milestones as part of the recovery plan developed by Seller, then Seller shall increase its efforts in order to remove or minimize such anticipated delay.

 

A-24


6.3

Restriction on Change Order for Extension of Delivery Date

Seller shall not be entitled to a Change Order for an extension of time under the Agreement and/or reimbursement of Costs to the extent that such extension or reimbursement is due to any act, omission or default on the part of Seller or any Subcontractor.

 

6.4

Delivery Delay Liquidated Damages

 

  (a)

Each Liquefaction Train and certain Deliverables have a Delivery Date. If Seller fails to deliver a Liquefaction Train or such Deliverable by its associated Delivery Date, as the Delivery Date may be extended according to a Change Order, Seller shall be obligated to pay to Buyer liquidated damages (the “Delivery Delay Liquidated Damages”) for delay in achieving the Delivery Date as from the first Day following the scheduled Delivery Date until the Day on which delivery of (i) that specific Liquefaction Train to the Delivery Point actually occurs, provided that Seller shall not be obligated to pay Delivery Delay Liquidated Damages for any Day (or part thereof) beyond [***] that is required for a Liquefaction Train to clear U.S. customs for reasons that are not attributable to Seller’s or its Subcontractors’ acts or omissions or (ii) that specific Deliverable to Buyer actually occurs.

 

  (b)

The Delivery Delay Liquidated Damages payable by Seller to Buyer for each Day of delay in delivery of a specific Deliverable to Buyer beyond the Delivery Date for such Deliverable is [***] per Day. The aggregate amount of the Delivery Delay Liquidated Damages payable by Seller to Buyer for all Deliverables shall not exceed [***].

 

  (c)

For each Liquefaction Train, the liquidated damages payable by Seller to Buyer for each Day of delay in delivery of the specific Liquefaction Train (in its entirety) to the Delivery Point beyond the Delivery Date is (i) in respect of the first [***] Liquefaction Trains to be delivered, an amount equal to: (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days; and (ii) in respect of the last [***] Liquefaction Trains, an amount equal to: (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days.

 

A-25


  (d)

The aggregate amount of Delivery Delay Liquidated Damages payable by Seller to Buyer for (i) each Liquefaction Train shall not exceed the applicable Delivery Delay Liquidated Damages Cap, and (ii) all Liquefaction Trains shall not exceed the Aggregate Delivery Delay Liquidated Damages Cap. Liquidated Damages payable by Seller to Buyer shall not exceed the Liquidated Damages Cap. Once Seller has accrued Delivery Delay Liquidated Damages in an amount equal to the Delivery Delay Liquidated Damages Cap or Aggregate Delivery Delay Liquidated Damages Cap, as applicable, Buyer shall be entitled to exercise the rights provided in Clause 6.5.

 

  (e)

Buyer shall invoice Seller for any amounts due for Delivery Delay Liquidated Damages. Payment of any Delivery Delay Liquidated Damages shall occur by Seller within [***] following the date Buyer submits to Seller an invoice therefore. Buyer and Seller agree that the amount of Delivery Delay Liquidated Damages are reasonable in light of the anticipated harm caused by the breach of duty related thereto and the difficulties of proof of loss and inconvenience or non-feasibility of obtaining any adequate remedy with respect to the actual level of damages Buyer is likely to suffer as the result of a Delivery Delay Event, and the Parties are estopped from contesting the validity or enforceability of such liquidated damages. Except as provided in Clause 28.1 and Clause 28.3, the payment of Delivery Delay Liquidated Damages during the period prior to the Delay Limit Date shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for any Delivery Delay Event. In the event the Delivery Delay Liquidated Damages provisions in the Agreement are found for any reason to be void, invalid or otherwise inoperative so as to disentitle Buyer from claiming and recovering Delivery Delay Liquidated Damages from Seller for any Delivery Delay Event, Buyer shall, in addition to the remedies set forth below in Clause 6.5, be entitled to claim against Seller and recover for damages for any Delivery Delay Event; provided that such damages shall not exceed the limitations set forth in Clause 6.4(d).

 

6.5

Delays – Other remedies

Notwithstanding Clause 6.2, if Seller has reached the Delay Limit Date, Buyer may by notice to Seller, at Buyer’s sole discretion:

 

  (a)

require Seller to agree, within [***] of Buyer’s demand, to remedy the Delivery Delay Event, within the period of time identified by Buyer, at Buyer’s sole discretion. If Seller fails to agree within [***] of Buyer’s demand, or fails to remedy the Delivery Delay Event within such agreed period(s), Buyer shall be free to exercise its rights or remedies under clause (b) hereafter; or

 

  (b)

terminate the Agreement in accordance with Clause 28.l(g) and seek to recover from Seller Buyer’s damages pursuant to Clause 28.3 (subject to the limit of liability cap in Clause 19.2) arising from the applicable Delivery Delay Event, and, upon such termination by Buyer, Seller shall deliver to Buyer the portions of the Liquefaction Train System for which Seller has received payment and which have not been delivered to the Delivery Point; provided, however, that Buyer shall not be entitled to terminate the Agreement for so long as Seller continues to pay Buyer the applicable Delivery Delay Liquidated Damages, despite the fact that the aggregate amount of Delivery Delay Liquidated Damages paid by Seller have exceeded the limitations set forth in Clause 6.4(d).

 

A-26


6.6

Issuance of LNTP and FNTP

The Project Schedule assumes that a limited notice to proceed (“LNTP”) authorizing the LNTP scope described in Appendix B (Pricing, Payment Terms & Cancellation Schedule) and Appendix C (Scope of Supply & Project Schedule) will be issued by Buyer no later than [***] Days prior to the issuance of the full notice to proceed authorizing Seller to proceed with the full scope of work under the Agreement (“FNTP”). If the LNTP is issued less than [***] Days prior to the issuance of the FNTP, the Project Schedule shall be extended day for day for each day that the LNTP was issued less than [***] Days prior to the issuance of the FNTP. In the event that no LNTP is issued prior to issuance of the FNTP, the Project Schedule shall be extended by [***] Days. Seller and Buyer acknowledge and agree that the amount payable under the LNTP shall be [***]. If Buyer fails to issue the FNTP within [***] Days following issuance of LNTP, Seller and Buyer shall jointly consider actions that can be taken prior to the issuance of FNTP to preserve schedule integrity with Major Subcontractors and facilitate the procurement of critical long-lead time equipment and materials (including Major Components). If Buyer fails to issue the FNTP within [***] Days following the Effective Date, Seller shall be entitled to a Change Order for, if the Project Schedule is adversely affected, an equitable adjustment to the Project Schedule. In addition, in such event Seller and Buyer shall jointly consider actions that can be taken following such [***] Day and prior to the issuance of FNTP to preserve subcontracts with Major Subcontractors and facilitate the procurement of critical long-lead time equipment and materials (including Major Components). If Buyer fails to issue the FNTP within [***] Days following the Effective Date, the senior management of Buyer and Seller shall meet within ten (10) Days thereafter to discuss when, if at all, the FNTP will be issued. If, after the senior management meeting there is no mutual agreement on extending the time for issuance of the FNTP, either Buyer or Seller may terminate the Agreement in which case Buyer shall pay Seller the applicable Termination Fee. Buyer may issue additional LNTPs for scope beyond what is provided in Appendix C (Scope of Supply & Project Schedule) pursuant to a Change Order issued pursuant to Clause 24.1.

 

6.7

Delivery Bonus

If Seller delivers a Liquefaction Train to Buyer at the Delivery Point on or before the date that is [***] Days prior to the relevant Delivery Date for such Liquefaction Train in the Project Schedule, then Buyer shall pay to Seller an amount equal to (i) in respect of the first [***] Liquefaction Trains, [***] for each such Liquefaction Train delivered to the Delivery Point prior to the Delivery Date provided for such Liquefaction Train, and (ii) in respect of the subsequent [***] Liquefaction Trains, [***] for each such Liquefaction

 

A-27


Train delivered to the Delivery Point prior to the Delivery Date provided for such Liquefaction Train, each of which amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement; provided, that in no event shall the total aggregate amount of all bonus amounts paid by Buyer under this Clause 6.7 exceed [***]. For the purposes of this Clause 6.7 only, Seller shall be deemed to have delivered any Liquefaction Train described in this Clause 6. 7 that is delivered to Buyer at the Delivery Point on or before the date that is at least [***] prior to the relevant Delivery Date for such Liquefaction Train in the Project Schedule notwithstanding that certain minor items forming a part of the Liquefaction Train have not been delivered to Buyer at the Delivery Point by such date; provided that (i) the Lender’s Engineer has confirmed to Buyer in writing (upon Buyer’s request) that the absence of such minor items would not reasonably be expected to adversely impact the project schedule for testing, commissioning, safety or operability of such Liquefaction Train and (ii) all such minor items are delivered to Buyer at the Delivery Point not later than the relevant Delivery Date for such Liquefaction Train in the Project Schedule or such other date as mutually agreed by the Parties in writing. Amounts earned by Seller pursuant to this Clause 6.7 shall be due and payable by Buyer to Seller upon the completion of delivery by Seller of all Components (as such term is defined in the PIS Purchase Order) of the power island system in accordance with the PIS Purchase Order.

 

7.

CONTRACT PRICE AND PAYMENT

 

7.1

Definition of Contract Price

A. The Contract Price is equal to the sum of [***]. The Contract Price, payment terms and cancellation schedule/charges for each individual Liquefaction Train is detailed in Appendix B (Pricing; Payment Terms & Cancellation Schedule). The Contract Price shall not include any duties and tariffs paid by Seller to deliver each Liquefaction Train to the Delivery Point (“Duties”) or the physical transportation costs set forth in Appendix K (Transportation Costs), exclusive of insurance costs and taxes associated with physical transportation costs other than Duties for each such Liquefaction Train (“Transportation Costs”). Buyer shall reimburse Seller for all reasonable, documented out-of-pocket Duties and Transportation Costs incurred by Seller plus a fixed fee of [***], payable in accordance with Appendix B (Pricing; Payment Terms & Cancellation Schedule). The Contract Price does not include any Buyer Taxes. Transportation Costs, inclusive of the fixed fee, shall not exceed [***] in the aggregate, provided that Seller has made commercially reasonable efforts to obtain competitive transportation pricing terms and to minimize transportation costs. Buyer hereby agrees to pay the Contract Price to Seller upon completion of the relevant Payment Milestones in accordance with the payment schedule (the “Payment Schedule”) set forth in Appendix B (Pricing; Payment Terms & Cancellation Schedule), in consideration for the performance by Seller of its related obligations under the Agreement.

 

A-28


B. The Contract Price shall be adjusted by an amount equal to the sum of (a) an amount reflecting changes in labor and commodities indices calculated in accordance with Part 1 of Appendix M (Contract Price Adjustments) and (b) a foreign exchange adjustment calculated in accordance with Part 2 of Appendix M (Contract Price Adjustments) between the Effective Date and the date of issuance of LNTP (or the date of issuance of FNTP in the event LNTP is not issued). The adjustments described in this paragraph shall be mutually agreed upon by the Parties in a Change Order as soon as reasonably practicable following issuance of LNTP (or if LNTP is not issued, following the issuance of FNTP for) and availability of Index 1 set forth in Part 1 of Appendix M (Contract Price Adjustments).

C. In the event that LNTP is issued and FNTP is not issued within [***] Days following the issuance of LNTP, then the Contract Price shall be adjusted further by an amount equal to the sum of (a) an amount reflecting changes in labor and commodities indices calculated in accordance with Part 3 of Appendix M (Contract Price Adjustments) and (b) a foreign exchange adjustment calculated in accordance with Part 4 of Appendix M (Contract Price Adjustments) between the date that is [***] Days after issuance of LNTP and date of issuance of FNTP. The adjustments described in this paragraph shall be mutually agreed upon by the Parties in a Change Order as soon as reasonably practicable following issuance of FNTP and availability of Index set forth in Part 3 of Appendix M (Contract Price Adjustments).

D. Payment of undisputed amounts of the Contract Price owed to Seller shall be made by Buyer thirty (30) Days from Buyer’s receipt of an invoice from Seller following completion of the relevant Payment Milestone(s) and receipt of all the relevant documentation, in accordance with the Agreement, and shall be remitted by wire transfer to the following account: [***]

 

7.2

Currency

Except as otherwise provided in the Agreement, payment shall be made by Buyer in Dollars, upon the completion of the individual Payment Milestones as set out in the Agreement and after Buyer’s receipt of an invoice for such Payment Milestones, reasonable evidence of the completion of such Payment Milestones, Lien waiver and releases in accordance with Clause 7 .6, and other specified documentation required under the Agreement.

 

A-29


7.3

Late Payments

Any undisputed amounts due and unpaid by either Party to the other Party shall bear interest commencing when such payment is due at a rate equal to the lesser of (a) [***] above the per annum Prime Rate reported daily in The Wall Street Journal, or (b) the maximum rate permitted by applicable Law, on all amounts not timely paid in accordance with the Agreement. The payment of interest is in addition, and not in lieu, of a Party’s right to suspend its performance or terminate the Agreement, as provided for under the Agreement.

 

7.4

Payment of Subcontractors

Seller shall pay each Subcontractor, save for disputes between Seller and any Subcontractor, the amount to which Subcontractor is entitled in accordance with the terms and conditions of the Agreement between Seller and such Subcontractor.

 

7.5

Set Off Rights

Each Party shall have the right at any time or from time to time, to set off against any amount due to the other Party under the Agreement any amount due from the other Party under the Agreement, including any amounts due because of breach of the Agreement. Buyer may, after written notice to Seller, withhold payment on an invoice or a portion thereof in the event of a failure of Seller to perform the Payment Milestone related to the payment being requested under such invoice, until such time as such Payment Milestone has been completed by Seller in accordance with the provisions of the Agreement. The written notice to Seller shall reasonably describe the failure of Seller and requirements necessary under the Agreement to complete the Payment Milestone.

 

7.6

Invoice Documentation

As a condition precedent to the obligation of Buyer to make each payment under the Agreement, Seller shall deliver with each invoice for each payment, a partial Lien waiver and release in the form of Appendix J-1 (Seller Form of Partial Lien Waiver and Release) in exchange for the current payment, and a partial Lien waiver and release in the form of Appendix J-3 (Subcontractor Form of Partial Lien Waiver and Release) from each Subcontractor; provided however, if such invoice is the invoice for the final payment under the Agreement, Seller shall be obligated to provide Buyer a final Lien waiver and release in the form of Appendix J-2 (Seller Form of Final Lien Waiver and Release), in exchange for the final payment, and a final Lien waiver and release in the form of Appendix J-4

 

A-30


(Subcontractor Form of Final Lien Waiver and Release) from each such Subcontractor, in exchange for the final payment. In addition to the final Lien waivers and releases from each Subcontractor, Seller shall provide, with such final invoice, an affidavit setting forth: (a) all amounts paid to each Subcontractor; (b) all amounts owed to each Subcontractor, if any; and (c) any amounts in dispute under any subcontract.

 

7.7

No Liens

To the extent that Buyer has timely paid Seller under the Agreement, Seller shall (a) not directly or indirectly create, incur, assume, or suffer to be created by it or any Subcontractor, employee, laborer, materialman, or other supplier of goods or services any Liens on or in respect of a Liquefaction Train, the Site, the Facility or any part thereof or interest therein, or against any party, and (b) promptly pay and/or discharge of record any Lien or other charges that, if unpaid, might be or become a Lien on a Liquefaction Train, the Site, the Facility or any part thereof or interest therein. Seller shall pay when due all amounts payable for labor and materials furnished in connection with the Agreement to prevent any Lien or other claim in respect of such labor and materials from arising. Seller shall immediately notify Buyer of the assertion of any Lien on a Liquefaction Train, the Site, the Facility or any part thereof or interest therein. Upon the failure of Seller to promptly pay, discharge, or provide security reasonably acceptable to Buyer for any Lien on a Liquefaction Train, the Site, the Facility or any part thereof or interest therein in respect of which Seller has been timely paid in accordance with the Agreement, within ten (10) Working Days of notice of the existence thereof from any source, Buyer may, but shall not be obligated to, pay or discharge such Lien and, upon the payment or discharge thereof, shall be entitled to immediately recover from Seller the amount thereof together with expenses incurred by it in connection with such payment or discharge or to set off all such amounts against any such sums owed by Buyer to Seller under the Agreement.

 

7.8

Buyer Credit Support

Within thirty (30) Days of the Effective Date, Buyer will provide a Buyer Parent Company Guarantee substantially in the form of Appendix D (Form of Buyer Parent Company Guarantee) issued by Buyer’s parent company in favor of Seller and covering Buyer’s payment obligations under the Agreement. The initial Buyer Parent Company Guarantee shall remain valid until the earlier of (i) the assignment of the Agreement to the EPC Contractor in accordance with Clause 4 or (ii) Financial Closing, at which time the Buyer Parent Company Guarantee shall be of no further force and effect and Seller shall return the original Buyer Parent Company Guarantee to Buyer. If the Agreement is assigned by Owner to the EPC Contractor, the EPC Contractor (in its capacity as Buyer) will provide a Buyer Parent Company Guarantee substantially in the form of Appendix D (Form of Buyer Parent Company Guarantee) issued by the EPC Contractor’s parent company in favor of Seller and up to an amount equal to the Contract Price, which Buyer Parent Company Guarantee shall remain valid until receipt by Seller of the final payment of the Contract Price.

 

A-31


7.9

Seller Credit Support

Within thirty (30) Days of the Effective Date the Agreement, Seller shall provide a Seller Parent Company Guarantee substantially in the form of Appendix H (Form of Seller Parent Company Guarantee) issued by Seller’s Guarantor in favor of Buyer and covering Seller’s obligations under the Agreement.

 

7.10

Payment Not Acceptance

No partial or final payment made by Buyer shall be construed as a waiver of any breach hereof by Seller or as an acceptance of defective portions of the performance by Seller hereunder or of any of the performance of Seller’s obligations hereunder that does not strictly comply with all requirements of the Agreement.

 

8.

TAXES AND DUTIES

 

8.1

Seller Taxes; Buyer Taxes

Seller shall be responsible for and shall pay all Seller Taxes. Buyer shall be responsible for and shall pay all Buyer Taxes (or reimburse Seller for Buyer Taxes in the event Seller is required to remit any Buyer Taxes directly to taxing authorities). If Buyer deducts or withholds Seller Taxes from the Contract Price, for each deducted or withheld amount of Seller Taxes, Buyer shall provide Seller, within thirty (30) Days from payment of Seller Taxes, with the official receipt issued by the appropriate Governmental Authority to which Seller Taxes have been paid or an alternative document acceptable to the relevant tax authorities. In respect of taxes to be withheld, if any, Buyer shall comply with any applicable bilateral conventions against double taxation. If Buyer requires tax residence certificates from Seller to apply an exempted or reduced tax regime, Seller shall submit the appropriate certificates, upon Buyer’s written request. If Buyer, under the applicable Laws of any country other than Seller’s country of incorporation, deducts or withholds Seller Taxes, Buyer shall pay additional amounts to Seller so that Seller receives the full amount of the Contract Price, as though no such Seller Taxes had been deducted or withheld.

 

8.2

Exemptions

If either Party benefits from any tax, fee or Duty exemption (a “Benefitted Party”) applicable to the other Party or its Subcontractors (the “Other Party”), such Benefitted Party agrees to provide the Other Party, without charge, before invoicing, or before any other relevant event, documentation acceptable to supporting the tax or customs authorities supporting the exemption, together with instructions for the Other Party on the procedure for the exemption. Pursuant to state Law, certain tax and incentive programs are available to qualifying manufacturers in certain circumstances, including the Louisiana Quality Jobs Program, Enterprise Zone Program, and the Manufacturing Machinery and Equipment sales tax exclusion (collectively, the “Rebatable Louisiana Sales and Use Tax”). Owner has not determined which, if any, of these programs it will pursue. Seller shall cooperate with and assist Buyer and Owner and any designated tax and incentive consultant, and shall require Subcontractors to cooperate with and assist Buyer and Owner and any designated

 

A-32


tax and incentive consultant, in obtaining tax and incentive benefits under these and any other available programs. Such assistance may include, but is not limited to, documenting purchase transactions, providing reports and supporting documents required to be submitted to obtain the tax and incentive benefits, and acting as agent for Owner in connection with the purchase of manufacturing machinery and equipment. If the determination of the proper amount of such Rebatable Louisiana Sales and Use Tax assessed on the Seller work is dependent upon knowing the actual cost incurred by Seller or its Subcontractors for the compensation of such Seller work, that portion of the audit devoted to reviewing the actual cost incurred by Seller or its Subcontractors for such Seller work shall be performed by Buyer or Owner’s tax consultant, which shall be retained by Buyer or Owner at Owner’s sole expense. The Parties agree that (unless the amount of Rebatable Louisiana Sales and Use Tax properly payable for the Seller work is subject to audit, litigation, arbitration, subpoena or summons issued by a Governmental Authority) such tax consultant shall not disclose to Buyer or Owner the actual cost incurred by Seller or its Subcontractors for such work, but the Parties agree that such tax consultant may report to Buyer or Owner the proper Rebatable Louisiana Sales and Use Taxes properly payable under Applicable Law. No access to documents shall be granted to Buyer or Owner’s tax consultant until such tax consultant has signed a confidentiality agreement with Seller and any applicable Subcontractor with terms customary in the audit industry for audits of this kind.

 

8.3

No Taxes Included

The Contract Price does not include any Buyer Taxes. Therefore if any Buyer Taxes are required to be collected by Seller, such Buyer Taxes will be added to the Contract Price. For Country sales and use tax, and in other jurisdictions where applicable, Buyer may report or remit sales taxes or similar taxes directly if Buyer timely provides a direct pay or exemption certificate to Seller.

 

8.4

Exemptions for Steel and Aluminum Imports

Seller shall provide all reasonably requested support and assistance to Owner and Buyer related to such filings (including any joint filings by Owner and Seller or its Affiliates) or deliverables that are necessary or appropriate to request an exclusion or exemption from the remedies instituted in Presidential Proclamations Adjusting Imports of Steel Into the United States and Adjusting Imports of Aluminum Into the United States under Section 232 of the Trade Expansion Act of 1962 or similar tariff measures; although Seller does not guarantee that it will achieve any particular results related to Seller’s support so provided. Such assistance may include, but is not limited to, documenting purchase transactions and providing reports and supporting documents required to be submitted to obtain the exclusion or exemption. If and to the extent the same would (to Seller’s knowledge) reasonably be expected to result in Buyer becoming liable hereunder for the payment of additional amounts in relation to tariffs or Duties, Seller shall consult with Buyer in good faith in relation to the selection of an alternative Approved Subcontractor not located in Asia.

 

A-33


9.

DELIVERY, TITLE TRANSFER, RISK OF LOSS, STORAGE

 

9.1

Delivery

Seller shall deliver equipment for each Liquefaction Train DDP the marine offloading facility(ies) adjacent to the Site as designated by Buyer to Seller for the items to be delivered by ocean vessel/barge (lncoterms 2010) and DDP the Site for the items to be delivered by truck (Incoterms 2010) (collectively, the “Delivery Point”). Except for those obligations expressly set forth in the applicable Incoterms 2010 or as specifically provided under the Agreement, Seller shall not be liable in any claim asserted by Buyer with respect to delivery of the Liquefaction Trains beyond the Delivery Point. The date of delivery for each Liquefaction Train is the date on which the Liquefaction Train in its entirety is delivered in accordance with this Clause 9.1 per the Incoterms to the Delivery Point. For the avoidance of doubt, delivery of an individual Liquefaction Train for purposes of the Agreement shall occur only when Seller has complied with all of its delivery obligations hereunder for that individual Liquefaction Train in its entirety. Except as otherwise provided in the Project Schedule or authorized in writing by Buyer, Seller shall not deliver the Liquefaction Trains (as provided in the Project Schedule) to the Delivery Point in each case more than [***] prior to the last day on which Buyer, in each case, would be entitled to payment of a bonus pursuant to Clause 6.7. Upon delivery, Buyer shall unload delivered items within a reasonable time, and for all ocean vessel/barge shipments no later than [***] from delivery.

 

9.2

Seller Replacement of Non-Conforming Items

If after delivery to the Delivery Point, Buyer discovers any item of a Liquefaction Train that has been damaged prior to delivery or that fails to conform with the requirements of the Agreement, then after receiving written notification of such non-conformance, the Seller shall promptly repair or replace such item or items, at Seller’s sole cost and expense in accordance with Clause 17.

 

9.3

Title; Risk of Loss

Title to each item of the Liquefaction Train shall pass from the Seller to the Buyer as follows:

 

  (a)

for each such item shipped from within the United States, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9.4, upon the earlier of (i) when Seller makes such item available for shipment from the warehouse or from the manufacturer’s factory and (ii) payment by Buyer to Seller for such item;

 

  (b)

for each such item shipped from the European Union, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9.4, upon the earlier of (i) when such item has been cleared for export, or (ii) when such item departs from the territorial land, sea and overlying airspace of the country from which such item is shipped; and

 

A-34


  (c)

for each such item shipped from within any other country, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9 .4, when such item departs from the territorial land, sea and overlying airspace of the country from which such item is shipped.

Seller shall maintain the risk of loss of each Liquefaction Train until such Liquefaction Train is delivered to the Delivery Point. Buyer shall only be responsible for risk of loss of each Liquefaction Train once such Liquefaction Train has been properly delivered to the Delivery Point.

 

9.4

Storage Locations

If any Liquefaction Train cannot be delivered to Buyer in accordance with the delivery terms herein due to Buyer’s request or any cause attributable to Buyer or its Affiliates and its or their officers, servants, agents, employees, sub-contractors, suppliers, and/or assigns, including transportation, staging, storage, or shipping service providers, upon notice to Buyer, Seller may ship such Liquefaction Train to a storage location mutually agreed to by Buyer and Seller; provided that Seller is not obligated to store or maintain any Liquefaction Train at Seller’s site past the Delivery Date for such Liquefaction Train. If such Liquefaction Trains are placed in a storage location pursuant to the preceding sentence of this Clause 9.4, the following conditions shall apply: (a) any amount of the Contract Price otherwise payable to Seller upon delivery to the Delivery Point shall be invoiced by Seller and payable by Buyer within thirty (30) Days of receipt by Buyer of such invoice and related documentation, including certification by Seller as to cause for storage; (b) all reasonable and documented incremental expenses incurred by Seller, such as for preparation for and placement into storage, handling, inspection, preservation, insurance, storage, removal charges and any taxes shall be reimbursed by Buyer upon submission of Seller’s invoices and related documentation, including evidence of such incremental expenses; and (c) upon receipt of notice from Buyer and payment of all undisputed amounts due under this Clause 9, Seller shall resume delivery of the Liquefaction Trains to the originally agreed Delivery Point (and any transportation costs or Duties incurred in the transportation of the Liquefaction Trains from storage to the Delivery Point shall not be subject to the limitation on Transportation Costs set forth in Clause 7.1). In the event the storage period extends for longer than [***], the Parties shall reconvene to agree on the schedule to reach delivery. To the extent shipment to storage of any of the Liquefaction Trains causes a delay in Seller’s schedule for delivery of the remaining Liquefaction Trains to be delivered hereunder, then Seller shall have the right to request a Change Order for adjustment of the Delivery Date for such remaining Liquefaction Trains.

 

A-35


10.

SELLER’S OBLIGATIONS

 

10.1

Compliance with Law

Seller shall, in performing its obligations under the Agreement, comply in all respects with all applicable professional standards, permits and Laws, rules, codes and regulations and the Liquefaction Train System shall be in full compliance with all applicable professional standards, permits and Laws, rules, codes and regulations. Seller shall perform its obligations hereunder in accordance with the Project Schedule. Seller shall only use qualified personnel to perform its obligations hereunder. Seller shall be responsible for obtaining all licenses, permits and approvals from all Governmental Authorities that are required for Seller to perform its obligations under the Agreement.

 

11.

BUYER’S OBLIGATIONS

 

11.1

Access to and Possession of the Site

Access to the Site, including the use of Owner’s rights of way and easements, shall be granted to Seller by Buyer, only to the extent necessary and for the sole purpose of Seller performing its obligations under the Agreement.

 

11.2

Access not exclusive

The access to the Site provided by Buyer shall not be exclusive to Seller.

 

11.3

Personnel for Acceptance Tests

When each Liquefaction Train or Liquefaction Train System is ready for any acceptance or testing that is required under Appendix C (Scope of Supply & Project Schedule), Owner and/or Buyer shall provide the normal operating and maintenance personnel under the technical direction and supervision of Seller pursuant to the Services Agreement for such testing. For the avoidance of doubt, Seller’s personnel shall never be deemed to be Buyer’s or Owner’s employees, and vice versa.

 

11.4

Electricity, Water and Gas

Buyer shall be responsible at its own costs for the provision of all utilities, including but not limited to electricity, natural gas and water (including drinking water) for activities necessary to be performed on Site. Buyer shall also be responsible for and bear the costs of all arrangements for connection, metering and distribution.

 

11.5.

Organization on Site

Seller shall cause its personnel and its Subcontractor’s personnel to observe and comply with all safety and security protocols of Buyer when such personnel are on the Site, provided that Seller has been made aware of such safety and security protocols requirements.

 

A-36


12.

DOCUMENTATION BY SELLER

 

12.1

Reports

Seller shall prepare and submit to Buyer at the appropriate time the progress reports as detailed in Appendix C (Scope of Supply & Project Schedule). Seller shall submit all such other information and reports in relation to the Liquefaction Train System as Buyer shall reasonably request from time to time.

 

12.2

Submission of Technical Documentation

Appendix C (Scope of Supply & Project Schedule) specifies which Technical Documentation is to be submitted to Buyer by Seller. Seller shall submit such Technical Documentation to Buyer within the time required in Appendix C (Scope of Supply & Project Schedule). The Technical Documentation is required to be provided by Seller to Buyer. Buyer may give comments on any Technical Documentation submitted within [***] of Buyer’s receipt thereof, unless otherwise mutually agreed by Buyer and Seller, and Seller shall make the appropriate revisions to such Technical Documentation. The Technical Documentation shall include Seller’s standard Operation and Maintenance Manuals and the functional descriptions, in sufficient detail, to enable competent personnel to operate, maintain and repair the Liquefaction Train System.

 

12.3

Errors in Technical Documentation

Seller shall be liable for any Costs incurred in correcting any discrepancies, errors or omissions in the Technical Documentation prepared by it or its Subcontractors or on their behalf.

 

13.

MACHINERY, EQUIPMENT, SPARE PARTS AND WORKMANSHIP

 

13.1

Manner of Execution

The Liquefaction Train System shall be manufactured in the manner set out herein, including Clause 5, and in Appendix C (Scope of Supply & Project Schedule).

 

13.2

Quality of Materials

The Liquefaction Train System shall be brand new and unused, and all parts and components thereof shall be brand new and unused, upon delivery and shall in any event be in accordance with the standards and other requirements set forth in the Agreement.

 

A-37


13.3

Spare Parts

Not later than [***] prior to the Delivery Date of the first Liquefaction Train under the Agreement, Seller shall deliver to Buyer a detailed list and pricing proposal for all Subcontractor and Seller-recommended spare parts for operating and maintaining the Liquefaction Train System (including components and systems of each such Liquefaction Train System) (“Spare Parts”). Within [***] thereafter, Buyer shall specify in writing (via a Change Order) which items on the list of Spare Parts it wishes to purchase and the time (in accordance with Seller’s proposal) when such items should be delivered to a location designated by Buyer. The amount due from Buyer to Seller in connection with Spare Parts shall be based on current market prices.

 

14.

TESTING AND RIGHT TO INSPECT DURING MANUFACTURING

 

14.1

Documents

Seller documents that are included as Deliverables in Appendix C (Scope of Supply & Project Schedule) and annotated with an “A”, including Technical Documentation, shall be submitted to Buyer for approval, in accordance with the Project Schedule. Such documents shall be submitted to Buyer in substantially complete packages for each Liquefaction Train to be delivered hereunder.

 

14.2

Inspection and testing during manufacturing

Each Buyer Inspection Party shall be entitled during the manufacturing of the Liquefaction Train System to inspect and examine the materials and workmanship in accordance with the inspection test plan to be mutually agreed upon in accordance with Appendix C (Scope of Supply & Project Schedule), to attend any scheduled test of the Liquefaction Train System (or major components thereof) on Seller’s premises during working hours, and to check the progress of manufacture of the Liquefaction Train System (or major items thereof) to be supplied under the Agreement during normal business hours. If components of the Liquefaction Train System are being manufactured on other premises, Seller shall, upon receipt of written request from Buyer or Owner, make commercially reasonable efforts to obtain for the Buyer Inspection Parties permission to inspect, examine and attend any test, provided that such inspection, examination or attendance of tests shall not delay the execution of the works (without prejudice to Clause 14.3). Such inspection, examination or attendance of tests, if made, shall not grant access to areas of Seller’s facilities not related to the execution of Seller’s obligations under Appendix C (Scope of Supply & Project Schedule) or where other work of a proprietary nature is being performed.

 

14.3

Dates for inspection and testing

 

  (a)

Each Buyer Inspection Party shall have the right to witness such activity of inspection or testing required in accordance with Appendix C (Scope of Supply & Project Schedule). Buyer and Owner each shall have the right to ask for additional witness points during the manufacturing of the Liquefaction Trains, subject to Seller’s right to request a Change Order for any adverse impact on the delivery of the Liquefaction Trains as a result of such additional witness points.

 

A-38


  (b)

The Parties shall agree (at least thirty (30) Days prior to the proposed date) on the date on, and the place at, which the Liquefaction Train System and/or portion(s)/module(s) will be ready for inspection and/or testing. Should any postponement become necessary, Seller shall provide written notification of the same at least three (3) Working Days prior to the originally scheduled date. Each of Buyer and Owner shall give Seller two (2) Working Days’ notice in writing of its intention to attend the tests, or ask for a postponement of not more than twenty-four (24) hours if required.

 

  (c)

Should Buyer or Owner not attend the tests at the place and on the date which Seller has stated in its notice, Seller may proceed with the tests and shall forthwith forward to Buyer and/or Owner the test results.

 

  (d)

If Buyer or Owner decides, at receipt of the test results, that the test should be repeated in its presence ( even though the test results, in the opinion of Seller, were satisfactory), all the consequences of such repeat test (additional Cost and delay suffered by Seller) shall be borne by Buyer, unless such repeat tests give results materially not in accordance with the Agreement, in which case they shall be borne by Seller. If, however, neither Buyer or Owner notifies Seller, within five (5) Working Days after receipt of the test results, that it has decided that the test should be repeated in its presence, Seller shall not be obliged to repeat such test.

 

  (e)

Seller shall provide at least ten (10) Days’ advance notification to Buyer or a third party, acting on Buyer’s behalf, of any inspection or test in accordance with the procedures set forth in Appendix E (Quality Assurance and Quality Control). Buyer and Owner shall have the right to add by written notice to Seller witness points and/or holding points, either for Buyer or Owner or any such third party.

 

14.4

General right to inspect during manufacturing

Each Buyer Inspection Party shall be entitled to inspect the Liquefaction Train System during Seller’s manufacturing at Seller’s facilities, during working hours after having given to Seller a reasonable notice. Any inspection of the Liquefaction Train System by any Buyer Inspection Party shall not release Seller from any obligation under the Agreement nor constitute an acceptance by Buyer or any other party of any portion of the Liquefaction Train System inspected or tested.

 

14.5

Certificate of testing

As and when the Liquefaction Train System shall have passed the factory acceptance testing referred to in Clause 1.6 of Appendix C (Scope of Supply & Project Schedule) during the manufacturing (the “Factory Acceptance Tests”), Seller shall, within thirty (30) days following completion of any Factory Acceptance Test, whether such Factory Acceptance Test passed or failed, provide the factory report with all required supporting data (including any anomalies encountered during the Factory Acceptance Test), signed by Seller and the factory performing such Factory Acceptance Tests and deliver the same to Buyer. All reports and related documentation associated with the Factory Acceptance Tests shall be stored in the manufacturing data books prepared in accordance with Seller’s standard practice, and all such manufacturing data books will be finally delivered to Buyer in electronic form no later than ninety (90) days after the final Delivery Date.

 

A-39


14.6

Failure on tests or inspection

If as a result of any inspection, examination or test of the Liquefaction Train System, Buyer or Owner, as the case may be, shall consider with reasonable justification that the Liquefaction Train System and/or portion(s)/module(s) contain any Defect or is not in accordance with the Agreement, Buyer or Owner, as the case may be, shall notify Seller accordingly stating in writing its objection and reasons therefore. Seller shall promptly investigate Buyer’s or Owner’s claim, and if a Defect is found to exist, Seller shall rework and reperform its obligations under Appendix C (Scope of Supply & Project Schedule) necessary to remedy the Defect and bring the results of Seller’s performance of its obligations under Appendix C (Scope of Supply & Project Schedule) back in conformance with the requirements of the Agreement. Thereafter, if a Defect in any component of a Liquefaction Train is discovered before the delivery of such Liquefaction Train to the Delivery Point, if requested by Buyer or Owner, as the case may be, the necessary tests not passed shall be repeated under the same terms and conditions, provided that all Costs resulting from the repetition of the tests shall be for Seller’s account.

 

14.7

Right to inspect by others

In exercising its rights to inspect the Liquefaction Train System and/or to attend any tests under the Agreement, each of Buyer and Owner shall, upon consent of Seller and at Buyer’s cost, be entitled to be accompanied by any Lenders, Lender’s Engineer, advisor(s) of Buyer, or any adjusters or insurers’ representatives, provided that such accompanying Persons may be first required by Seller to enter a separate non-disclosure agreement with Seller. Seller shall allow all such Persons the same rights of inspection and test attendance as are enjoyed by Buyer or Owner pursuant to the Agreement, whether or not such inspection or attendance is made with Buyer or Owner, provided that such Persons may be first required by Seller to enter a separate non-disclosure agreement with Seller.

 

15.

DELIVERY OF THE LIQUEFACTION TRAINS

 

15.1

Delivery

Unless Buyer shall otherwise direct, no Liquefaction Train shall be delivered except in accordance with the schedule of Delivery Dates in the Project Schedule.

 

15.2

Packing and Marking

The Liquefaction Train System and/or portion(s)/module(s) shall be packed in boxes/containers or packing/packaging in accordance with Seller’s standards set forth in Appendix C (Scope of Supply & Project Schedule).

 

A-40


15.3

Detailed specification and procedure

On or before ten (10) Days prior to the Delivery Date of a component of a Liquefaction Train, Seller shall prepare and submit to Buyer, for information and approval, the detailed specification of packing and marking, specify the type and number of documents to be prepared and transmitted, with the form for each of them, all in accordance with the Agreement. Not less than ninety (90) Days prior to the first Delivery Date, the Parties shall meet and discuss the shipping procedures, including marking, cargo list preservation, preservation requirements and other related matters.

 

15.4

Warranty of ownership

Seller warrants and guarantees title to the Liquefaction Train System provided under the Agreement, and Seller warrants and guarantees that title and ownership thereto shall pass to and vest in Buyer, as agreed in the Agreement, free and clear of any and all Liens.

 

16.

COMPLIANCE WITH LAWS, CODES AND STANDARDS

 

16.1

Contract Price Basis

The Contract Price is based on Seller’s design, manufacture, testing and delivery of the Liquefaction Train System pursuant to:

 

  (a)

Seller’s design criteria, manufacturing processes and procedures and quality assurance program;

 

  (b)

those industry specifications, codes and standards that are (i) identified in Appendix C (Scope of Supply & Project Schedule) or (ii) otherwise applicable to the Liquefaction Train System or Seller’s obligations under the Agreement;

 

  (c)

those Laws in effect as of the Effective Date, which are applicable to the Liquefaction Train System or Seller’s obligations under the Agreement; and

 

  (d)

the specifications and other requirements contained in the Agreement, including Appendix C (Scope of Supply & Project Schedule).

 

16.2

Export Controls

The Parties agree to comply with all applicable export control and economic sanctions Laws in the performance of the Agreement, including any restrictions or conditions regarding the export, re-export, or other transfer of the Deliverables under the Agreement that are in effect now or are hereafter imposed by the any Governmental Authority. Each Party shall be responsible for its own compliance with applicable export control and economic sanctions Laws with regards to their Affiliates, employees, facilities and activities. These restrictions and conditions include, but are not limited to, (a) restrictions and export licensing requirements governing the export, re-export, or other transfer to other persons, entities, or countries of the Deliverables under the Agreement, (b) restrictions and

 

A-41


export licensing requirements governing the export or other transfer of foreign-developed information that incorporates the Deliverables under the Agreement, (c) any applicable restrictions on the export, re-export, or other transfer of the Deliverables under the Agreement to countries and Persons that are subject to applicable sanctions, embargoes, or other prohibitions, and (d) any applicable restrictions on the export or other transfer of the direct product of technical data. Each Party shall notify the other Party in writing prior to transferring any commodity, software or technology that is: (i) controlled at a level greater than EAR99 or Anti-Terrorism controls under the Export Administration Regulations (“EAR”); or (ii) subject to the jurisdiction of an export control regime other than the EAR. Seller acknowledges that, in connection with the performance of the Agreement, the export and customs Laws and regulations of the Country apply to the furnishing and shipment of the Liquefaction Train System.

 

16.3

Nuclear Activity Restrictions

The Liquefaction Train System sold hereunder is not intended for application (and shall not be used) in connection with any nuclear installation or activity and Buyer warrants that it shall not use the Liquefaction Train System for such purposes, or permit others to use or permit others to use the Liquefaction Train System for any such purposes. If, in breach of the foregoing, any such use of the Liquefaction Train System sold hereunder occurs, Seller shall have no liability for any nuclear or other damage, injury or contamination, and Buyer shall indemnify Seller, its Affiliates and suppliers of every type and tier against any such liability, whether arising as a result of breach of contract, warranty, indemnity, tort (including negligence), strict liability or otherwise.

 

16.4

Required Authorizations

Notwithstanding any other provisions herein, Seller shall be responsible for timely obtaining of any required authorization, such as an import license, foreign exchange permit, work permit or any other authorization from a Governmental Authority that are required for Seller to perform its obligations under the Agreement.

 

16.5

Anti – Corruption

 

  (a)

Each Party represents, warrants and covenants to the other Party that neither the representing Party, nor any of its Affiliates (or any of their respective principals, partners or funding sources), is currently (i) a Person designated by the U.S. Department of Treasury’s Office of Foreign Assets Control as a “specially designated national or blocked person” (“SDN”) or similar status, (ii) a person otherwise identified by a government or legal authority as a person with whom the other Party is prohibited from transacting business; (iii) directly or indirectly owned or controlled by an SDN or the government of any country that is subject to an embargo by the government of the Country; or (iv) a Person acting on behalf of an SDN or a government of any country that is subject to an embargo by the government of the Country. Each Party agrees that it will notify the other Party in writing immediately upon the occurrence of any event that subsequently results in any of the designations set forth in this Clause 16.5(a).

 

A-42


  (b)

Each Party shall, in the performance of the Agreement, comply with all Laws, orders, directives, and regulations in effect on the Effective Date and as they may be amended from time to time that are applicable to such Party. Notwithstanding anything contained herein to the contrary, the Agreement shall not be interpreted or applied so as to require either Party to do, or to refrain from doing, anything that would constitute a violation of federal or state laws and regulations applicable to it, including the Foreign Corrupt Practices Act of 1977, 15 U.S.C. § 78dd-2, the OECD Anti-Bribery Convention, the U.K. Bribery Act of 2010, E.U. and E.U. member country anti-bribery and corruption laws, laws or regulations restricting participation in or compliance with certain foreign boycotts, directly or indirectly, as contained in the U.S. Export Administration Act of 1979, the U.S. Internal Revenue Code or any similar statute, regulation, order or convention binding on such Party, as each may be amended from time to time, and including implementing regulations promulgated pursuant thereto (collectively, the “Anti-Corruption Laws”). Without limiting the foregoing, each Party agrees on behalf of itself, its Affiliates and their respective directors, officers, employees, agents and contractors, not to pay any fees, commissions or rebates to any employee, officer or agent of the other Party or its Affiliates or their respective shareholders, or provide or cause to be provided to any of them any gifts or entertainment of significant cost or value in connection with the Agreement or in order to influence or induce any actions or inactions in connection with the commercial activities of the Parties in connection with the Agreement.

 

  (c)

Each Party represents, warrants and covenants with respect to itself and its Affiliates that (i) it and its Affiliates are being and have been operated in compliance in all material respects with the Anti-Corruption Laws, (ii) neither it nor any of its Affiliates has received any written notice or claim alleging any material violation under any of the Anti-Corruption Laws, and (iii) neither it nor any of its Affiliates, nor any of their respective directors, officers, or employees (or, to the best of the representing Party’s knowledge and belief, any partner, intermediary or other Person acting or purporting to act on behalf of such Party or any of its Affiliates) has knowingly directly or indirectly paid, offered, given, promised to pay or authorized the payment of any money or anything of value to (A) any candidate for public office, any past or present employee, director, officer, official, representative or agent of any government, government or legal authority, instrumentality, or any public international organization (“Government Official”), (B) any Person acting for or on behalf of any Government Official, or (C) any other Person at the suggestion, request, direction or for the benefit of any of the above-described Persons to obtain, retain or direct business or to obtain special concessions or pay for favorable treatment for business secured or for special concessions already obtained.

 

A-43


  (d)

Neither Seller, nor any of its Affiliates, directors, officers, employees or agents, shall use its relationship with Buyer to attempt to disguise the sources of illegally-obtained funds. Seller further represents and warrants that no such attempt of the sort described in this Clause 16.5(d) has been made prior to the Effective Date.

 

  (e)

Each Party shall keep all records necessary to confirm compliance with this Clause 16.5 for a period of five (5) years following the year for which such records apply. If a Party asserts that the other Party is not in compliance with this Clause 16.5, the asserting Party shall notify the other Party indicating the type of non-compliance asserted. After such notification, the asserting Party may cause an independent auditor to audit the records of the other Party in respect of the asserted non-compliance. The costs of any independent auditor under this Clause 16.5(e) shall be paid (i) by the audited Party, if such Party is determined not to be in compliance with this Clause 16.5 or (ii) by the asserting Party, if the other Party is determined to be in compliance with this Clause 16.5.

 

  (f)

Seller agrees to indemnify, defend, release and hold Buyer, Buyer’s Parties and its and their shareholders, directors, officers, employees, agents, consultants or representatives harmless from any penalties and fines assessed by government authorities arising out Seller’s breach of any or all of this Clause 16.5. Buyer agrees to indemnify, defend, release and hold Seller Parties harmless from any penalties and fines assessed by government authorities arising out Buyer’s breach of any or all of this Clause 16.5. Any breach of any of the representations, warranties and covenants in this Clause 16.5 shall be grounds for termination of the Agreement, and if Seller is the breaching Party, there shall be no further payments due to Seller upon termination.

 

17.

WARRANTY

 

17.1

Warranty; Warranty Period

 

  (a)

Seller warrants to Buyer that (i) each Liquefaction Train shall be (A) free from defects in material, workmanship and title and (B) designed, engineered and manufactured in accordance with applicable Laws, the specifications referenced in the Agreement and the other requirements of the Agreement, and (ii) the performance by Seller of its obligations under Appendix C (Scope of Supply & Project Schedule) shall be free from defects and performed in accordance with applicable Laws and the other requirements of the Agreement. Except as set forth in Clause 17.2, the “Warranty Period” for the warranties in this Clause 17.1 shall be the period starting on the date of Substantial Completion of the Liquefaction Train for the first Liquefaction Train and ending upon the earlier of (1) [***] after the date of Substantial Completion of the Liquefaction Train System and (2) [***] from the date that Seller delivered the applicable Liquefaction Train to the Delivery Point, provided that Buyer and Seller shall enter into the Preservation Agreement, for any Liquefaction Trains that are shipped to storage, if the storage period is for a period greater than [***].

 

A-44


  (b)

Buyer may, from time to time during the Warranty Period, issue a Change Order (and Seller shall execute such Change Order) extending the Warranty Period for one (1) or more Liquefaction Trains for the number of months specified in such Change Order such total extension not to exceed [***]. Such Change Order shall increase the Contract Price by an amount equal to [***] per Month for each Month that the Warranty Period for [***] Liquefaction Trains is extended by Buyer pursuant to the preceding sentence.

 

17.2

Remedial Actions

 

  (a)

If a failure to meet any of the warranties set forth in Clause 17.1 appears within the Warranty Period, Buyer shall promptly notify Seller in writing and make the defective component available for correction/inspection within a commercially reasonably time period thereafter. Seller, at its expense, shall thereafter correct any Defect by: (i) re-performing the defective performance of its obligations under Appendix C (Scope of Supply & Project Schedule); and (ii) repairing or replacing the defective Liquefaction Train System(s) or components thereof. Seller shall not be responsible for material removal or replacement of systems, structures or other parts of the Facility to grant Seller access to the Liquefaction Train System. Any repair, replacement or re-performance by Seller hereunder shall extend the applicable Warranty Period on such repaired, replaced or re-performed component of the Liquefaction Train System for a period of [***], provided that in no event shall the Warranty Period extend beyond [***] from the date of Substantial Completion of the Liquefaction Train System. Such warranty extension is in lieu of and not in addition to the extension of the Warranty Period for Serial Defects contemplated in Clause 17.2(c).

 

  (b)

Seller shall not be liable for Defects that arise after the Warranty Period, as extended hereunder, has expired. The testing of any replaced or repaired parts of the Liquefaction Train System, equipment or components shall be performed in the same manner as originally contemplated under the Agreement, and Buyer shall be notified of and may be represented at all tests that may be made. Seller shall not be responsible for the removal or replacement of any systems, structures or other parts of Buyer’s facility, which were not provided by Seller, in order for Seller to gain access to the Liquefaction Train System.

 

  (c)

If, prior to the expiration of the Warranty Period, [***] of the same component of the Liquefaction Train System experience a Defect of an identical or nearly identical nature that causes or could reasonably be expected to cause an outage of a Liquefaction Train (herein, a “Serial Defect”), then Seller shall examine the cause of the Serial Defect and (i) undertake technical analysis of the underlying problem in order to determine (A) the root cause of such Serial Defect and (B) the repairs or replacements that may be required to avoid future occurrences of such Serial Defect, (ii) prepare and provide to Buyer and Owner a written report setting

 

A-45


  forth the results of such analysis, (iii) promptly redesign if necessary and repair or replace any Liquefaction Train, as necessary, and (iv) if such Serial Defect root cause requires redesign, repair or replacement of the defective component or Liquefaction Train, extend the Warranty Period for such redesigned, repaired or replaced component for an additional period of [***], all at no additional cost to Buyer or Owner. Such warranty extension for Serial Defects is in lieu of and not in addition to the extension of the Warranty Period contemplated in Clause 17.2(a).

 

  (d)

If Seller fails to commence the corrective work for any Defects, Serial Defects or damage within a reasonable period of time not to exceed [***] after receiving notification by Buyer or Owner regarding such Defect, Serial Defect or damage, Buyer or Owner, at their sole discretion, may (in addition to any other remedies that each of them have under the Agreement) proceed to commence to correct such Defect, Serial Defect or damage at Seller’s risk and expense and the Costs incurred by Buyer or Owner, as the case may be, in performing such corrective work shall be paid by Seller.

 

17.3

Warranty Conditions

Seller does not warrant the Liquefaction Train System or any repaired or replaced parts against normal wear and tear or from the involvement in an accident. The warranties and remedies set forth herein are further conditioned upon:

 

  (a)

the proper storage (to the extent it is the responsibility of Buyer or its Affiliates and its or their officers, servants, agents, employees, sub-contractors, suppliers, and/or assigns, including transportation, staging or storage, or shipping service providers), installation, operation, and maintenance of the Liquefaction Train System in conformance with the operation instruction and installation manuals (including revisions thereto) provided by Seller; and

 

  (b)

repair or modification of the Liquefaction Train System pursuant to Seller’s instructions or approval.

Seller does not warrant any equipment or services of others designated by Buyer where such equipment or services are not normally supplied by Seller.

 

17.4

Warranties Exclusive

[***], THE PRECEDING PARAGRAPHS OF THIS CLAUSE 17 SET FORTH THE EXCLUSIVE REMEDIES FOR ALL CLAIMS BASED ON FAILURE OF OR DEFECT IN THE LIQUEFACTION TRAIN SYSTEM OR PERFORMANCE OF SELLER’S OBLIGATIONS UNDER APPENDIX C (SCOPE OF SUPPLY) PROVIDED UNDER THE AGREEMENT, WHETHER THE

 

A-46


FAILURE OR DEFECT ARISES BEFORE OR DURING THE WARRANTY PERIOD AND WHETHER A CLAIM, HOWEVER INSTITUTED, IS BASED ON CONTRACT, INDEMNITY, WARRANTY, TORT/EXTRA-CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY OR OTHERWISE. THE FOREGOING WARRANTIES ARE EXCLUSIVE AND ARE IN LIEU OF ALL OTHER WARRANTIES, CONDITIONS AND GUARANTEES WHETHER WRITTEN, ORAL, IMPLIED OR STATUTORY. NO IMPLIED STATUTORY WARRANTY OR MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE SHALL APPLY.

 

18.

INTELLECTUAL PROPERTY

 

18.1

Work Product

Any concept, idea, product, process, technique, discovery, improvement, know-how, work of authorship (including without limitation documents, specifications, calculations, maps, sketches, notes, reports, data, models, samples, drawings, designs, videos and electronic software) or other information, including the Technical Documentation, in each case whether subject to copyright registration or patent protection or not, other than Seller Developed Intellectual Property, that was first conceived, reduced to practice or created by Seller or any of its employees or Subcontractors in the performance of its obligations hereunder and (a) was furnished by Seller to Buyer as a Deliverable under the Agreement or (b) is an improvement to or otherwise incorporates Buyer’s Background Intellectual Property or Buyer’s Developed Intellectual Property (collectively, “Work Product”) shall be the sole property of Buyer. Seller agrees to assign and hereby assigns to Buyer all rights, title and interest throughout the world in and to all Work Product, including all Intellectual Property therein.

 

18.2

Background Intellectual Property

As between the Parties, each Party exclusively owns all right, title, interest in the Background Intellectual Property created or acquired by it. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty-free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses to the rights granted to Buyer under this Clause 18.2 and to freely transfer the rights granted to Buyer under this Clause 18.2 to third parties, other than to Seller’s Competitors) [***]. Seller expressly reserves all other rights in Seller Background Intellectual Property. Buyer hereby grants to Seller and Seller’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights [***].

 

A-47


18.3

Seller Developed Intellectual Property

As between Seller and Buyer, all improvements to the Background Intellectual Property of Seller that are first conceived, reduced to practice or created by Seller or any of its employees or Subcontractors in the performance of Seller’s obligations under the Agreement (the “Seller Developed Intellectual Property”) shall be owned by Seller, subject to Buyer’s rights in any Background Intellectual Property of Buyer contained therein. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses and to freely transfer the rights granted to Buyer under this Clause 18.3 to third parties other than the Seller Competitors) [***]. Seller expressly reserves all other rights in Seller Developed Intellectual Property.

 

18.4

Buyer Developed Intellectual Property

As between Seller and Buyer, all improvements to the Background Intellectual Property of Buyer that are first conceived, reduced to practice or created by Buyer or any of its employees, contractors or consultants in the performance of Buyer’s obligations under the Agreement (the “Buyer Developed Intellectual Property”) shall be owned by Buyer, subject to Seller’s rights in any Background Intellectual Property of Seller contained therein.

 

18.5

Instruments of Service

All reports, design drawings, specifications, field data and notes, calculations, estimates and other documents prepared in the performance of Seller’s obligations under the Agreement by Seller or any of its employees or Subcontractors as instruments of service, other than any such items that are Work Product and other than any items that include Buyer Developed Intellectual Property and/or Buyer’s Background Intellectual Property (collectively, the “Instruments of Service”), shall remain Seller’s property. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights [***].

 

A-48


18.6

Outside Intellectual Property

(a) Seller shall not use any trade secret, invention, work of authorship, software, patent or protectable design conceived or developed by a party other than Buyer or Seller (collectively, the “Outside Intellectual Property”) in connection with the Agreement unless Seller has secured the rights to use such Outside Intellectual Property for the benefit of Buyer. To the extent Seller uses such Outside Intellectual Property in connection with the Agreement and to the extent that Seller has the legal and contractual right to do so, Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses to the rights granted to Buyer under this Clause 18.6 and to freely transfer the rights granted to Buyer under this Clause 18.6 to third parties) [***].

(b) Upon Buyer’s request, Seller agrees to provide, without any additional charge, a copy of the Exchanger Design and Rating native file for the dynamic simulation of the Liquefaction Train (the “EDR File”) generated by the supplier of the Cold Boxes. Subject to Clause 22, Buyer shall have the right to use the EDR File for the sole purpose of (i) [***] and (ii) [***]. Except for the use rights set forth herein, nothing in this Agreement is deemed to grant or transfer any Intellectual Property Rights in the EDR File to Buyer. The EDR File shall not be considered a Deliverable and shall be provided by Seller “AS IS” without warranties of any kind.

 

18.7

Restrictions on Use

Except to the extent required by applicable Law, copies of any Work Product, Seller Developed Intellectual Property or Instruments of Service shall not be released to any other party by Seller, or to any Seller Competitors, or used by Seller for any purpose that is unrelated to the Facility, except in response to a subpoena, court order or other legal process, or to the extent that the foregoing materials were already within the public domain or in the possession of third parties, without the prior written approval of Buyer, which Buyer may withhold in its sole and absolute discretion and excepting that the Parties agree that the restrictions on use in this Clause 18 shall not preclude Seller from using, and Buyer specifically agrees, that Seller retains rights to use (including on subsequent projects or scopes of work with third parties) the Seller’s Know-How, Seller Developed Intellectual Property and Instruments of Service, but subject to the confidentiality obligations set forth in Clause 22. At the expiration or earlier termination of the Agreement, Seller shall promptly deliver to Buyer (but in any event, no later than thirty (30) Days from the date of such expiration or termination) all of the Work Product in all forms and formats including without limitation hard copies and electronic files on disks.

 

A-49


18.8

Notification and Indemnification

If either Party is made the subject of any Intellectual Property Claim, such Party shall promptly notify the other Party in writing. Buyer shall defend and indemnify Seller against those Intellectual Property Claims only to the extent that Seller’s allegedly infringing or misappropriating conduct is expressly requested in writing by Buyer. This indemnity shall not extend to any conduct of Seller which is discretionary to Seller. Seller shall defend, indemnify and hold the Buyer Parties harmless against any Losses arising from any Intellectual Property Claim. In no event shall Seller have such indemnity obligations for any Intellectual Property Claim arising from or in connection with any material modification by Buyer that was not authorized by Seller. Buyer shall (a) promptly notify Seller in writing of its receipt of such Intellectual Property Claim and (b) make no admission of liability and ( c) not take any position materially adverse to Seller regarding such Intellectual Property Claim. Without limiting the foregoing, Seller shall, at its own expense and option, promptly, but in no event later than thirty (30) Days following the date of notice from Buyer (i) settle or defend the claim or any suit or proceeding and pay all damages and costs awarded in it against Buyer, (ii) procure for Buyer or reimburse Buyer for procuring, the right to continue using the deliverables from Seller’s performance of its obligations under the Agreement, including the infringing service, the Technical Documentation, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim, (iii) modify such infringing deliverables, including the Technical Documentation, service, materials, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim so that they become non-infringing or (iv) replace the infringing deliverables, including any Technical Documentation, service, materials, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim with non-infringing deliverables to the satisfaction of Buyer; provided that in no case shall Seller take any action which adversely affects Buyer’s continued use and enjoyment of the applicable service, materials, Work Product, or other Intellectual Property without the prior written consent of Buyer. Buyer’s acceptance of the materials, Deliverables, Work Product, and other equipment or any other component of Seller’s performance under the Agreement shall not be construed to relieve Seller of any obligation hereunder. The Buyer Parties agree to cooperate and assist Seller in the defense of any Intellectual Property Claims, at Seller’s cost. Any Buyer Party which seeks to settle any Intellectual Property Claim shall seek the prior approval of Seller, which approval shall not be unreasonably withheld, conditioned, or delayed, in respect of such settlement.

 

18.9

Seller Simulation Models

Upon Buyer’s request, Seller agrees to provide, if and when requested by Buyer, without any additional charge, one permit for permission based access to Seller’s web-based service that provides access to a copy of the Liquefaction Train transient simulation model created, conceived or developed by Seller or any of its employees or Subcontractors based on a Subcontractor proprietary software named [***] (the

 

A-50


“BH-Transient Liquefaction Train Simulation Model”), and, subject to Clause 22, Seller hereby grants to Buyer and Buyer’s Affiliates a, royalty free, non-transferable, non-sublicensable, worldwide, fully paid-up, non-exclusive license rights [***]. The BR-Transient Liquefaction Train Simulation Model shall not be considered a Deliverable and shall be provided by Seller “AS IS” without warranties of any kind.

18.10 Survival

The provisions of Clause 18 shall survive the completion or early termination of the Agreement.

 

19.

INDEMNITY AND LIMITATION OF LIABILITY

 

19.1

Indemnification

 

  (a)

Seller shall indemnify, defend, release and hold harmless the Buyer Parties from any physical damage to property of third parties or injury to Persons, including death, to the extent resulting directly from the negligence or willful misconduct of Seller or its officers, servants, agents, employees, and/or assigns while engaged in activities relating to the Agreement. Buyer shall indemnify, defend, release and hold harmless the Seller Parties from any physical damage to property of third parties or injury to Persons, including death, to the extent resulting directly from the negligence or willful misconduct of Buyer, its officers, servants, agents, employees, and or assigns, while engaged in activities relating to the Agreement. In the event such damage or injury is caused by the joint or concurrent negligence of Seller and Buyer, the loss shall be borne by each Party in proportion to its negligence.

 

  (b)

For the purposes of this Clause 19.1 no portion of the Facility or the Site shall be considered third party property and Buyer and Owner release claims related to property damage to the Facility or the Site caused by Seller (and including those property damage claims caused by Seller’s negligence or willful misconduct); provided, however, Seller shall, to the extent directly caused by the negligence or willful misconduct of Seller, be responsible to Buyer and Owner (subject to the limitations of Clause 19.2 and Clause 19.3) for: [***].

 

A-51


19.2

Limit of Liability

EXCEPT, WITH RESPECT TO [***], THE TOTAL LIABILITY OF EACH PARTY FOR ALL CLAIMS OF ANY KIND, WHETHER IN CONTRACT, WARRANTY, INDEMNITY, TORT/EXTRA-CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY, OR OTHERWISE, ARISING OUT OF OR RELATING TO THE PERFORMANCE OR BREACH OF THE AGREEMENT OR USE OF THE LIQUEFACTION TRAIN SYSTEM, SHALL NOT EXCEED [***]. BUYER’S PAYMENT OF THE CONTRACT PRICE SHALL NOT COUNT TOWARDS BUYER’S CONTRACT PRICE LIMIT OF LIABILITY HEREUNDER. FURTHER, WITH RESPECT TO SELLER’S FAILURE TO ACHIEVE (1) EACH OF THE LIQUEFACTION TRAIN PERFORMANCE GUARANTEES AND (2) EACH OF THE LIQUEFACTION TRAIN SYSTEM PERFORMANCE GUARANTEES, BUYER AGREES, AFTER ANY TERMINATION OF THE AGREEMENT BY BUYER, NOT TO ASSERT ANY CLAIMS AGAINST SELLER FOR MONETARY DAMAGES IN EXCESS OF [***]. FOR THE AVOIDANCE OF DOUBT, SELLER’S OBLIGATIONS UNDER A CLAIM FOR SPECIFIC PERFORMANCE ARE NOT LIMITED BY THIS CLAUSE 19.2.

 

19.3

Waiver of Consequential Damages

IN NO EVENT, WHETHER AS A RESULT OF BREACH OF CONTRACT, WARRANTY, INDEMNITY, TORT/EXTRA CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY, OR OTHERWISE, SHALL EITHER PARTY OR ITS SUBCONTRACTORS OR SUPPLIERS BE LIABLE FOR LOSS OF PROFIT OR REVENUES, LOSS OF USE OF THE LIQUEFACTION TRAIN

 

A-52


SYSTEM OR ANY ASSOCIATED EQUIPMENT, DOWNTIME COSTS, CLAIMS OF A PARTY’S CUSTOMERS FOR SUCH DAMAGES, OR FOR ANY SPECIAL, CONSEQUENTIAL, INCIDENTAL, INDIRECT OR EXEMPLARY DAMAGES. THE WAIVERS SET FORTH IN THIS CLAUSE 19.3 SHALL NOT APPLY TO LIQUIDATED DAMAGES OR ANY THIRD PARTY INDEMNIFICATION CLAIMS UNDER THE AGREEMENT, PROVIDED THAT EACH OF THE SELLER EXCLUDED PARTIES AND BUYER EXCLUDED PARTIES SHALL NOT BE DEEMED A THIRD PARTY FOR THE PURPOSES OF THIS CLAUSE 19.3.

 

19.4

Seller Protection from Third Parties

If Buyer is furnishing Seller’s Liquefaction Train System to a third party by contract or using Seller’s Liquefaction Train System at a facility owned by a third party, Buyer shall [***].

 

20.

DISPUTE RESOLUTION

 

20.1

Disputes

Any dispute, controversy or claim between the Parties that arises out of, under or in connection with the Agreement, including its interpretation, performance, enforcement, termination, validity or breach ( each a “Dispute”) shall be subject to resolution under this Clause 20, which shall be the exclusive dispute resolution method for any such Dispute. A Party wishing to declare a Dispute shall deliver to the other Party a notice identifying the disputed issue (a “Notice of Dispute”). Following the delivery of a Notice of Dispute, the Parties shall attempt in good faith to resolve such Dispute promptly through negotiation. If the Dispute has not been resolved within thirty (30) Days after the date on which the Notice of Dispute was delivered, then any Party shall be permitted to submit such Dispute to binding arbitration in accordance with Clause 20.2.

 

20.2

Arbitration

Any Dispute that is not resolved pursuant to Clause 20.1 shall be exclusively and definitively resolved through final and binding arbitration conducted in accordance with the Rules of Arbitration of the International Chamber of Commerce (the “ICC Rules”), which ( except as modified by this Clause 20.2) are deemed to be incorporated by reference into this Clause 20.2.

 

A-53


  (a)

The arbitration tribunal shall consist of three (3) arbitrators. One (1) arbitrator shall be appointed by Buyer, one (1) arbitrator shall be appointed by Seller, and the third arbitrator shall be selected by agreement of the first two (2) arbitrators. If either of the first two (2) appointments is not made within thirty (30) Days after the request for arbitration, or if the first two (2) arbitrators fail to agree on a third arbitrator within thirty (30) Days after the later of them has been appointed, the unfilled appointment will be made, at the request of either Party, by the ICC. No arbitrator appointed pursuant to this Clause 20.2(a) shall be an employee, agent, contractor, competitor or former employee, agent or contractor of, or have or have had any material interest (directly or indirectly) in the business of or in any Party or any of its Affiliates. Each arbitrator shall be knowledgeable with respect to engineering, procurement and construction contracts and shall be fluent in the English language.

 

  (b)

Unless the Parties agree in writing otherwise:

 

  (i)

the seat of arbitration shall be New York, New York, and the language to be used in the proceedings shall be English;

 

  (ii)

the arbitrators shall, by majority vote, render a written award stating the reasons for their award within three (3) Months after any hearing conducted has been concluded. The arbitral award may contain such orders (including orders for specific performance, setoff, other equitable relief or monetary damages) in respect of or affecting any of the Parties (and/or any direct loss or damage suffered by any of them), as such arbitrators determine to be appropriate in the circumstances; provided that, except as expressly permitted by the terms of the Agreement, the arbitrators shall not have the authority to award any indirect, consequential or punitive damages;

 

  (iii)

the Parties and the arbitral tribunal will ensure that the arbitration proceedings and any documents disclosed in such proceedings are kept strictly confidential; and

 

  (iv)

the responsibility for the costs of the arbitration will be determined by the arbitral tribunal.

 

  (c)

An arbitral award rendered in accordance with this Clause 20.2 shall be final and binding on the Parties. The Parties agree that any arbitral award made pursuant to this Clause 20.2 may be enforced against the Parties or their assets wherever they may be found and that a judgment upon the arbitral award may be entered (and any other applicable relief, including interlocutory relief, may be granted) in any court having jurisdiction on such matters, and subject to their respective obligations contained elsewhere in the Agreement, shall take all such actions as are necessary to give full and complete effect to the award which, in accordance with its terms, shall be binding upon and enforceable against them. The Parties may make an application to any court for the obtaining of any evidence (whether by discovery of documents, interrogatories, affidavits or testimony of witnesses or whatsoever), which the arbitrators direct shall be admitted in the arbitral proceedings.

 

A-54


  (d)

No Party shall be entitled to suspend its performance under the Agreement during the pendency of any Dispute or during the period during which any defaulting Party is attempting to remedy its non-performance of the Agreement within the periods prescribed therefor in Clause 28.

 

  (e)

Nothing contained in this Clause 20 shall be construed to prohibit any Party from making an application to any court of competent jurisdiction for an order of specific performance or for other injunctive or equitable relief as long as the arbitral tribunal contemplated in Clause 20.2 has not yet been formed.

 

20.3

No Consolidation

Unless the Parties otherwise agree, no dispute, controversy or claim hereunder shall be consolidated with any other arbitration proceeding involving any third party.

 

21.

GOVERNING LAW

The validity, construction and performance of the Agreement shall be governed by and construed in accordance with the laws of the State of New York, without regard to the conflict oflaw provisions thereof that would require the application of the laws of any other jurisdiction.

 

22.

CONFIDENTIALITY

 

22.1

Confidential Information

In connection with the Agreement, each Party (as to information disclosed, the “Disclosing Party“) may each provide the other Party (as to information received, the “Receiving Party”) with Confidential Information. “Confidential Information” means:

 

  (a)

all pricing for Liquefaction Train System;

 

  (b)

all information that is designated in writing as “confidential” or “proprietary” by Disclosing Party at the time of written disclosure, except Work Product; and

 

  (c)

all information that is orally designated as “confidential” or “proprietary” by Disclosing Party at the time of oral disclosure and is confirmed to be “confidential” or “proprietary” in writing within ten (10) Days after oral disclosure, except Work Product.

Any Confidential Information disclosed or revealed by the Disclosing Party shall remain the Disclosing Party’s property and the Receiving Party shall not use such Confidential Information for its own benefit or for the benefit of any third party nor shall the Receiving Party disclose to any third party any such Confidential Information disclosed or revealed to it by the Disclosing Party, except as permitted under the Agreement. The Receiving Party shall take every reasonable precaution to protect the confidentiality of Confidential Information.

 

A-55


The obligations of this Clause 22.1 shall not apply as to any portion of the Confidential Information that:

 

  (i)

is or becomes generally available to the public other than from disclosure by Receiving Party, its representatives or its Affiliates;

 

  (ii)

is or becomes available to Receiving Party or its representatives or Affiliates on a non-confidential basis from a source other than Disclosing Party when the source is not, to the best of Receiving Party’s knowledge, subject to a confidentiality obligation to Disclosing Party;

 

  (iii)

is independently developed by Receiving Party, its representatives or Affiliates, without reference to the Confidential Information;

 

  (iv)

is required to be disclosed by Law, a valid legal process or a Governmental Authority;

 

  (v)

is approved for disclosure in writing by an authorized representative of Disclosing Party;

 

  (vi)

is disclosed by Seller to its Affiliates and each of their agents, advisors, employees, consultants, contractors, officers, directors and representatives (collectively, the “Seller’s Representatives”) to the extent necessary to evaluate the Facility and provided that each such Seller’s Representative is advised of the confidential nature of such Confidential Information and agrees to be bound by provisions consistent with the provisions of the Agreement or is bound by professional obligations of confidentiality;

 

  (vii)

is disclosed by Buyer to Owner, Owner’s Affiliates and each of their agents, advisors, employees, consultants, contractors, officers, directors, representatives, existing or potential investors, Lenders and existing or potential off takers (and their respective consultants, advisors and agents) (collectively, the “Buyer’s Representatives”) to the extent necessary to evaluate the Facility and provided that each such Buyer’s Representative is advised of the confidential nature of such Confidential Information and agrees to be bound by provisions consistent with the provisions of the Agreement or is bound by professional obligations of confidentiality; or

 

  (viii)

is disclosed by Buyer or Owner to any Governmental Authority in connection with the Facility.

 

A-56


22.2

Restrictions on Use

Receiving Party agrees:

 

  (a)

to use the Confidential Information only as permitted under the Agreement;

 

  (b)

to take reasonable measures to prevent disclosure of the Confidential Information, except as permitted under the Agreement; and

 

  (c)

not to disclose the Confidential Information to any Person other than its Representatives.

Any Confidential Information disclosed or revealed by the Disclosing Party shall remain the Disclosing Party’s property. Receiving Party agrees to obtain a commitment from any recipient of Confidential Information to comply with the terms of this Clause 22. Confidential Information shall not be reproduced without Disclosing Party’s written consent, and upon expiration or termination of the Agreement, the Receiving Party shall return to the Disclosing Party all Confidential Information in its possession or control, except to the extent that the Agreement entitles Receiving Party to retain the Confidential Information; provided, however, that the return of such Confidential Information shall not affect the license rights granted to Buyer pursuant to Clause 18.

 

22.3

Disclosure

If Receiving Party or any of its Affiliates or Representatives is required to disclose any Confidential Information pursuant to Clause 22. l(iv), the Receiving Party agrees to provide Disclosing Party with prompt written notice to permit Disclosing Party to seek an appropriate protective order or agency decision or to waive compliance by Receiving Party with the provisions of this Clause 22. In the event that efforts to secure confidential treatment are unsuccessful, Receiving Party may, to the extent lawful, revise the Confidential Information to make it non-proprietary or to minimize the loss of its proprietary value.

 

22.4

No License

Nothing in Clause 22 grants Receiving Party any license to any invention, patent, trademark or copyright now or later owned or controlled by Disclosing Party.

 

22.5

Available Remedies

Each Party acknowledges that money damages would not be a sufficient remedy for a breach of this Clause 22. The Parties acknowledge that any violation of this Clause 22 by the Receiving Party may cause the Disclosing Party irreparable harm that could not be fully remedied by monetary damages. Accordingly, if it appears that the Receiving Party has disclosed (or has threatened to disclose) Confidential Information in violation of the Agreement, the Disclosing Party shall have the right, in addition to, and not in lieu of, monetary damages or any other legal or equitable remedy available to it, to seek injunctive or other equitable relief from a court of competent jurisdiction, without the necessity of proving damages or posting any bond, as may be necessary to prevent any such violation.

 

A-57


22.6

No Public Announcements

Neither Party shall make any public announcement about the Agreement or related documents, including its existence, without prior written approval of the other Party.

 

22.7

Survival

As to any individual item of Confidential Information, the restrictions of this Clause 22 shall expire upon the earlier of five (5) years following the date of disclosure or three (3) years following termination or expiration of the Agreement, except with respect to Confidential Information that the Disclosing Party protects as a trade secret, for which the obligations set forth in this Clause 22 shall remain in effect as long as such Confidential Information remains a trade secret.

 

23.

INSURANCE

 

23.1

Policy Coverages

Seller shall secure, pay for, and provide, at no additional cost or expense to Buyer, the following insurance coverages during the term of the Agreement:

 

TYPE

  

AMOUNT

  

OTHER REQUIREMENTS

1. Workers’ Compensation and Employer’s Liability   

With respect to Workers’ Compensation:

Statutory Limits With respect to Employer’s Liability:

   1. No “alternative” forms of coverage will be permitted.
   [***] Bodily Injury by Accident - Each Accident   
   [***] Bodily Injury by Disease - Policy Limit   
   [***] Bodily Injury by Disease - Each Employee   
2. Commercial General Liability (Occurrence Basis)   

[***] per occurrence

[***] product-completed operations aggregate limit.

[***] personal and advertising injury limit.

[***] aggregate

  

1. ISO form CG 0001 10/01 or equivalent.

2. Buyer will be named as “additional insured” (ISO CG2010 11/85 edition or equivalent and providing additional insured status for on-going and completed operations). This coverage on a primary and non-contributory basis.

 

A-58


TYPE

  

AMOUNT

  

OTHER REQUIREMENTS

3. Business

Automobile

Liability

(Occurrence Basis)

   Combined single limit for bodily injury and property damage of $ [***] per occurrence or its equivalent.   

1. ISO form CA 0001 1001, or equivalent.

2. Buyer will be named as “additional insured”. This coverage on a primary and non- contributory basis.

3. Includes owned, hired and non-owned vehicles.

4. Umbrella

Liability

(Occurrence Basis)

   [***]   

1. Written on an umbrella basis above the coverage referenced above.

2. Same inception and expiration dates as commercial general liability insurance.

3. Waiver of subrogation in favor of Buyer.

5. Professional

Liability

(Claims-Made Basis)

  

[***] per claim/

[***] annual aggregate

  

1. No exclusion for bodily injury, property damage, asbestos or pollution liability (including mold).

2. Coverage must remain in place for a minimum of two (2) years after the date of Substantial Completion of the Facility.

6. Marine Cargo

Insurance

   [Highest value individual shipment]   

1. Inception from the time shipment first set in motion at Seller’s premises for imminent transit to the Site

2. No co-insurance clause.

3. Buyer will be named as “additional insured”

7. Personal

Property Insurance

  

[Amount at/exceeding value of

equipment being purchased]

   1. Seller shall cause the Person designated by Buyer to be duly designated, by means of amendments by endorsement in form and substance satisfactory to Buyer, to be first loss payee.

 

23.2

Certificates of Insurance

All commercial general liability and automobile liability insurance coverage shall be written on an occurrence-based or claims-made form. An original certificate of insurance in the accord form shall be delivered to Buyer and Owner within five ( 5) Days of the date of the Agreement, prior to commencement of performance under the Agreement or prior

 

A-59


to the payment of any amounts by Buyer hereunder, whichever occurs first. The certificate of insurance shall evidence insurance coverage at least in the minimum limits, or as may be further increased in connection with the requirements of the Agreement and contain an endorsement affording thirty (30) Days prior written notice to Buyer and Owner by certified mail in the event of cancellation or non-renewal of coverage and ten (10) Days written notice to Buyer and Owner by certified mail in the event of nonpayment of the premium.

 

23.3

Additional Insureds

At no expense to Buyer, Seller shall name Buyer and other Buyer Parties (as such are reasonably designated by Buyer) as an additional insured to the extent of Seller’s obligations under the Agreement on all liability insurance policies required hereunder (other than Professional Liability and Employer’s Liability insurance). Seller acknowledges Seller’s obligation to obtain appropriate insurance coverages for the benefit of Seller (and Seller’s employees, if any). If Seller fails to comply with the obligations for insurance required herein, Buyer shall have the right, but not the obligation, to purchase such insurance at Seller’s sole cost and expense and shall invoice, withhold payment or back charge Seller for the cost incurred by Buyer to satisfy such obligations. Seller waives any rights to recovery from Buyer for any injuries that Seller (and/or Seller’s employees) may sustain while performing Seller’s obligations under the Agreement and that are a result of the negligence of Seller or Seller’s employees. Likewise, Buyer waives any rights to recovery from Seller for any injuries that Buyer (and/or Buyer’s employees) may sustain while performing Buyer’s obligations under the Agreement and that are a result of the negligence of Buyer or Buyer’s employees.

 

23.4

Buyer/Owner AU-Risk Insurance

At no expense to Seller, from and after Financial Closing, Buyer shall cause a Builder’s All-Risk insurance policy (“BAR Policy”) to be maintained in a coverage amount sufficient to cover the construction, commissioning, and testing of the Facility. Seller shall receive a waiver of subrogation to the extent of Buyer’s and Owner’s release and indemnity obligations contained in the Agreement.

 

24.

CHANGE ORDERS

 

24.1

Buyer Change Order

Buyer may, at any time, by written notice to Seller, request an addition to, or deletion from, or other changes in obligations of Seller under Appendix C (Scope of Supply & Project Schedule) and/or items and Deliverables that are to be provided by Seller hereunder, including alterations to the Liquefaction Train System schedule or scope. Seller shall review and reasonably consider such requested change and shall make a written response concerning such change to Buyer within ten (10) Days after receiving such request from Buyer to confirm if Seller will pursue cost and schedule analysis. Within twenty (20) Days of the requested change Seller, will provide a written response to include Seller’s estimated

 

A-60


lump-sum fixed cost associated with such requested change together with the estimated number of hours, average hourly rates and material quantities required to carry out such change. If the Parties agree upon such change, the Parties shall set forth the agreed-upon change in a written change order signed by all Parties in the form of Appendix I (a “Change Order”). Each Change Order shall constitute a final accord, satisfaction and settlement of all matters covered therein.

 

24.2

Seller Change Order

To the extent that (a) Seller experiences a Force Majeure Event or (b) a suspension is requested by Buyer in accordance with Clause 29 .3, or ( c) other circumstances occur which specifically entitle Seller to request a Change Order under the Agreement, if Seller desires to request an equitable adjustment to the Project Schedule and/or Contract Price, Seller shall give Buyer notice within fifteen (15) Days after Seller knows of the occurrence of the event or circumstances giving rise to such request. Within fifteen (15) Days after the delivery of such notice, Seller shall provide Buyer with a written notice setting forth the reasons why Seller believes the Project Schedule or Contract Price should be adjusted and the requested adjustment to the Project Schedule or Contract Price, such written response to include Seller’s estimated lump-sum fixed cost associated with such requested change together with the estimated number of hours and material quantities required to carry out such change. If Buyer does not agree with such requested adjustment, then Buyer shall notify Seller and such disagreement shall be resolved pursuant to the procedures set forth in Clause 20. If Buyer accepts any such requested adjustment to the Project Schedule or Contract Price, a Change Order shall be executed by the Parties and the Project Schedule or Contract Price shall be adjusted in accordance with the terms of such Change Order.

 

24.3

No Interruption of Performance

Except insofar as a Change Order was to specifically modify one or more provisions or conditions of the Agreement, all other provisions and conditions of the Agreement shall remain unaffected. No Change Order shall be deemed issued, or agreed upon, due to a course of dealing or course of the performance of any obligations hereunder, including the performance of any obligations pursuant to any other Change Order, individually or collectively. Seller shall not commence to perform, or perform, any obligations constituting a change from the obligations hereunder, and Buyer shall have no liability to Seller for any such obligations performed, unless Seller and Buyer have executed a Change Order. Seller shall not suspend, in whole or in part, performance of the Agreement during any dispute over any Change Order or a request for a Change Order unless directed to do so by Buyer, provided that Seller shall not be obligated to proceed with a disputed requested change or a disputed item under a Change Order, until such dispute is resolved, unless (a) such disputed requested change(s) or disputed item(s) (i) have an aggregate value of less than [***] or (ii) is required to address health and safety or environmental issues or (b) Seller elects, at its discretion, to proceed with such disputed requested change or disputed item while the dispute is still pending, provided, further, that, in each such case, Seller shall proceed, without waiving any rights with respect to such disputed requested change or disputed item.

 

A-61


25.

PERFORMANCE GUARANTEES, PERFORMANCE TESTS AND PERFORMANCE LIQUIDATED DAMAGES

 

25.1

Performance Guarantees

Seller guarantees to Buyer that the following Performance Guarantees shall be satisfied in accordance with Appendix F (Performance Tests):

 

  (a)

the LNG production capacity (measured in MTPA) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be equal to or greater than the Liquefaction Train Production Capacity Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train;

 

  (b)

the LNG production capacity (measured in lbs/hr) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be equal to or greater than the Liquefaction Train System Production Capacity Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date;

 

  (c)

(i) the minimum performance guarantee with respect to power demand (measured in kWh/Tonne) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train Power Demand Minimum Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train; and

(ii) the full performance guarantee with respect to power demand (measured in kWh/Tonne) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train Power Demand Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train;

 

  (d)

(i) the minimum performance guarantee with respect to power demand (measured in kWh/Tonne) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train System Power Demand Minimum Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date; and

 

A-62


(ii) the full performance guarantee with respect to power demand (measured in kWh/Tonne) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train System Power Demand Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date;

 

  (e)

the full performance guarantee with respect to any loss in Mixed Refrigerant (measured in standard liters/minute) for the Liquefaction Train System, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Refrigerant Losses Performance Guarantee prior to shipment from the manufacturing facility;

 

  (f)

the quality of the LNG produced by the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall satisfy the LNG Quality Performance Guarantee, on or before the Guaranteed Liquefaction Train System Substantial Completion Date; and

 

  (g)

The Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, will run at the required capacity to meet Facility demand over a [***] hour continuous test period with [***] equivalent availability factor that accounts for any capacity de-ratings during the test period (the “Reliability Guarantee”). Seller shall have a maximum of [***] test periods allotted to satisfy the Reliability Guarantee before a change of equipment or software is required. The Performance Test for the Reliability Guarantee will be run concurrently with tests in Clause 25.l(b).

 

25.2

Performance Tests

Seller shall conduct in accordance with Appendix F (Performance Tests) (a) the Liquefaction Train Performance Tests for an individual Liquefaction Train only after such Liquefaction Train has achieved Ready for Test and (b) the Liquefaction Train System Performance Tests only after the Liquefaction Train System has achieved Ready for Test. Seller shall conduct the Performance Tests for each of the Liquefaction Trains, individually, and the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, under the conditions and in strict accordance with the requirements set forth in Appendix F (Performance Tests). If (A) the Liquefaction Train Performance Tests of an individual Liquefaction Train demonstrate that the Liquefaction Train Performance Guarantees for such Liquefaction Train System have been achieved or (B) the Liquefaction Train System Performance Tests demonstrate that the Liquefaction Train System Performance Guarantees have been achieved, then Seller shall provide Buyer with written notice of such occurrence and shall provide Buyer with a test report, together with supporting documentation, demonstrating the achievement of the applicable Performance Guarantees within ten (10) Days of the date of the completion of such Performance Tests and upon receipt of such documentation Buyer shall, within ten (10) Days, either (A) confirm in writing to Seller the successful completion of the Liquefaction Train Performance Tests or the Liquefaction Train System Performance Tests or (B)

 

A-63


provide written notice to Seller of why Buyer disagrees that the Liquefaction Train Performance Guarantees or the Liquefaction Train System Performance Guarantees have been achieved. If any Performance Test indicates that an individual Liquefaction Train or the Liquefaction Train System fails to achieve any Performance Guarantee for reasons attributable to Seller, its Affiliates or Subcontractors, then Seller shall, at its own cost and expense, take appropriate corrective action and Seller shall thereafter reperform the Performance Test.

Seller’s obligation to meet the Liquefaction Train Performance Guarantees under this Clause 25 shall be satisfied when (i) all the Liquefaction Train Performance Tests have been completed, and (ii) either (1) such tests demonstrate that all Liquefaction Train Performance Guarantees are met or (2) such tests demonstrate that the Liquefaction Train Power Demand Minimum Performance Guarantee is met and Seller has paid all payable liquidated damages for the Liquefaction Train Performance Guarantees that are not met.

Seller’s obligation to meet the Liquefaction Train System Performance Guarantees under this Clause 25 shall be satisfied when (i) all the Liquefaction Train System Performance Tests have been completed, and (ii) either (1) such tests demonstrate that all Liquefaction Train System Performance Guarantees are met or (2) such tests demonstrate that the Liquefaction Train Power Demand Minimum Performance Guarantee and the Refrigerant Losses Performance Guarantee are met and Seller has paid all payable liquidated damages for the Liquefaction Train System Performance Guarantees that are not met.

At all times during start-up, testing and commissioning of the Liquefaction Train System, Owner may, at no expense to Seller, arrange for the disposition of the Facility’s LNG. Owner shall have all right, title and interest to all LNG produced by the Facility and all of the proceeds from the sale thereof.

 

25.3

Performance Liquidated Damages and Performance Delay Liquidated Damages

(a) Performance Liquidated Damages

 

  (i)

If Seller achieves the Liquefaction Train Power Demand Minimum Performance Guarantee but fails to achieve the Liquefaction Train Power Demand Performance Guarantee for a Liquefaction Train, then Seller shall pay to Buyer [***] for each kWh/Tonne of LNG produced above the Liquefaction Train Power Demand Performance Guarantee (the “Liquefaction Train Power Demand Liquidated Damages”).

 

  (ii)

If Seller achieves the Liquefaction Train System Power Demand Minimum Performance Guarantee but fails to achieve the Liquefaction Train System Power Demand Performance Guarantee, then Seller shall pay to Buyer [***] for each kWh/Tonne of LNG produced above the Liquefaction Train System Power Demand Performance Guarantee (the “Liquefaction Train System Power Demand Liquidated Damages”).

 

 

A-64


  (iii)

The total amount of Performance Liquidated Damages payable by Seller to Buyer shall not exceed the Performance Liquidated Damages Cap and the total amount of Liquidated Damages payable by Seller to Buyer shall not exceed the Liquidated Damages Cap. Once Seller has accrued (i) Performance Liquidated Damages in amount equal to the Performance Liquidated Damages Cap or (ii) Liquidated Damages in amount equal to the Liquidated Damages Cap [***].

 

  (iv)

The assessment of Liquefaction Train Power Demand Liquidated Damages will not apply concurrently with Liquefaction Train System Power Demand Liquidated Damages.

(b) Performance Delay Liquidated Damages

 

  (i)

If Seller fails to achieve the Liquefaction Train Production Capacity Performance Guarantee for a Liquefaction Train on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train, then Seller shall pay to Buyer an amount equal to: (x) in respect of the first [***] Liquefaction Trains to be performance tested, (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] for each Day of such delay for the next [***]; and (y) in respect of the remaining [***] Liquefaction Trains to be performance tested, (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] for each Day of such delay for the next [***] (the “Liquefaction Train Production Capacity Liquidated Damages”).

 

  (ii)

If Seller fails to achieve either the Liquefaction Train System Production Capacity Performance Guarantee, or the LNG Quality Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date, then Seller shall pay to Buyer an amount equal to (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each Day of such delay for the next [***] (the “Liquefaction Train System Production Capacity Liquidated Damages” or the “LNG Quality Liquidated Damages”, as applicable).

 

  (iii)

The aggregate amount of Performance Delay Liquidated Damages payable by Seller to Buyer for each Liquefaction Train shall not exceed the applicable Performance Delay Liquidated Damages Cap. The aggregate amount of Liquefaction Train System Production Capacity Liquidated Damages and LNG Quality Liquidated Damages payable shall not exceed, in the aggregate, the

 

A-65


Liquefaction Train System Performance Delay Liquidated Damages Cap. Once Seller has accrued (i) Performance Delay Liquidated Damages in amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (ii) Liquidated Damages in amount equal to the Liquidated Damages Cap [***].

 

  (c)

Buyer shall invoice Seller on a monthly basis for any amounts due for Performance Liquidated Damages and Performance Delay Liquidated Damages. Payment of any Performance Liquidated Damages and Performance Delay Liquidated Damages by Seller shall occur within ten (10) Business Days following the date Buyer submits to Seller an invoice therefore. Buyer and Seller agree that the amount of Performance Liquidated Damages and Performance Delay Liquidated Damages are reasonable in light of the anticipated harm caused by the breach of duty related thereto and the difficulties of proof of loss and inconvenience or non-feasibility of obtaining any adequate remedy with respect to the actual level of damages Buyer is likely to suffer in the event that Seller fails to achieve the (i) Liquefaction Train Power Demand Performance Guarantee, (ii) Liquefaction Train System Power Demand Performance Guarantee, or (iii)(A) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (B) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, and the Parties are estopped from contesting the validity or enforceability of such liquidated damages. Except as provided in Clause 28.1 and Clause 28.3, the payment of Performance Delay Liquidated Damages shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for Seller’s failure to achieve (w) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (x) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date. Except as provided in Clause 28.1 and Clause 28.3, the payment of Performance Liquidated Damages shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for Seller’s failure to achieve (y) the Liquefaction Train Power Demand Performance Guarantee or (z) the Liquefaction Train System Power Demand Performance Guarantee. In the event the Performance Liquidated Damages or Performance Delay Liquidated Damages provisions are found for any reason to be void, invalid or otherwise inoperative so as to disentitle Buyer from claiming and recovering Performance Liquidated Damages or Performance Delay Liquidated Damages from Seller, Buyer shall, in addition to the remedies set forth below in Clause 25.4, be entitled to claim against Seller and recover for damages for Seller’s failure to achieve (1) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train, (2) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, (3) Liquefaction Train Power Demand Performance Guarantee or (4) Liquefaction Train System Power Demand Performance Guarantee; provided that such damages shall not exceed, in the case of Clauses (1) and (2), the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, and, in the case of Clauses (3) and (4), the Performance Liquidated Damages Cap.

 

A-66


25.4

Buyer Remedies

If Seller has accrued an aggregate amount of (i) Performance Liquidated Damages in an amount equal to the Performance Liquidated Damages Cap, (ii) Performance Delay Liquidated Damages in an amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (iii) Liquidated Damages in an amount equal to the Liquidated Damages Cap, then Buyer may by notice to Seller, at Buyer’s sole discretion, either:

 

  (a)

[***]

 

  (b)

[***].

 

25.5

Performance Guarantees [***]

Seller acknowledges and agrees that its Unconditional Performance Obligation is [***].

 

A-67


26.

ACCESS AFTER DELIVERY

For the sole purpose of (and to the extent necessary for) performing its obligations under the Agreement regarding the remedying of Defects or guaranteed performance, Seller may request Buyer (who shall not unreasonably withhold its consent) to have the right of access to all parts of the Liquefaction Train System(s). Such access shall only be granted during normal working hours and will be limited to the duly authorized representatives of Seller, provided that (a) Seller shall, and shall cause its authorized agents, employees and inspectors to, at all times comply with Buyer’s safety and security requirements when present at the Site and (b) Seller shall not, and shall cause its authorized agents, employees and inspectors not to, interfere with the operation of any Liquefaction Train System or the Facility. Seller understands and acknowledges that the Liquefaction Trains will commence commercial operations prior to the Substantial Completion of the Facility.

 

27.

QUALITY ASSURANCE AND QUALITY CONTROL

The quality control exercised by Seller in its manufacture of the Liquefaction Train System shall be in accordance with the standards set forth in Appendix E (Quality Assurance and Quality Control).

 

28.

EVENTS OF DEFAULT; REMEDIES

 

28.1

Events of Default for Seller

Each of the following events constitutes an Event of Default of Seller under the Agreement:

 

  (a)

Seller fails to make when due any payment (other than amounts disputed in good faith) due and owing under the Agreement and such failure is not cured within ten (10) Working Days after Buyer notifies Seller of such failure;

 

  (b)

Seller is in material breach of its obligations under the Agreement ( other than an obligation to make payment or an obligation that is otherwise specifically set forth in this Clause 28.1 as a separate Event of Default) and such material breach is not remedied within thirty (30) Days after Buyer notifies Seller of such material breach, which notice sets forth in reasonable detail the nature of such material breach, provided that if such material breach is not reasonably capable of being remedied within the thirty (30) Day remedy period specified above but is reasonably capable of being remedied, Seller shall have an additional sixty (60) Day remedy period to remedy such material breach, so long as Seller promptly commences and thereafter diligently pursues such remedy;

 

  (c)

Seller fails to establish or maintain the credit support required under Clause 7.9, and such breach is not cured within ten (10) Working Days after written notice of such breach from Buyer;

 

A-68


  (d)

Any representation or warranty made by Seller in Clause 32.2 is not true in all material respects as of the date made and such inaccuracy is not cured within thirty (30) Days after Buyer notifies Seller of such inaccuracy, which notice sets forth in reasonable detail the nature of the inaccuracy;

 

  (e)

A Bankruptcy Event occurs with respect to Seller;

 

  (f)

Seller assigns the Agreement, except as described in Clause 4.1;

 

  (g)

If Seller has accrued an aggregate amount of Delivery Delay Liquidated Damages in an amount equal to the Delivery Delay Liquidated Damages Cap or Aggregate Delivery Delay Liquidated Damages Cap, as applicable, and has not delivered all of the Liquefaction Trains (in their entirety) to the Delivery Point; and

 

  (h)

If Seller has accrued an aggregate amount of (i) Performance Liquidated Damages in an amount equal to the Performance Liquidated Damages Cap, (ii) Performance Delay Liquidated Damages in an amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (iii) Liquidated Damages in an amount equal to the Liquidated Damages Cap and Seller has failed to achieve (A) the Liquefaction Train Performance Guarantees for any Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (B) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, (C) Liquefaction Train Power Demand Performance Guarantee or (D) Liquefaction Train System Power Demand Performance Guarantee.

If an Event of Default with respect to Seller has occurred, Buyer will have the right, but not the obligation, at any time when such Event of Default is continuing, to designate by notice to Seller a date for terminating the Agreement that will be no earlier than thirty (30) Days after the notice is deemed delivered. Upon the date designated as the termination date by Buyer as a result of an Event of Default of Seller, Buyer shall suspend any further payment to Seller under the Agreement.

 

28.2

Events of Default for Buyer

Each of the following events constitutes an Event of Default of Buyer under the Agreement:

 

  (a)

Buyer fails to make when due any payment (other than amounts disputed in good faith) due and owing under the Agreement and such failure is not cured within ten (10) Working Days after Seller notifies Buyer of such failure;

 

A-69


  (b)

Buyer is in material breach of its obligations under the Agreement (other than an obligation to make payment or an obligation that is otherwise specifically set forth in this Clause 28.2 as a separate Event of Default) and such material breach is not remedied within thirty (30) Days after Seller notifies Buyer of such material breach, or if such material breach cannot be reasonably remedied within such thirty (30) Day period, Buyer has not commenced to cure such material breach within thirty (30) Days of notice from Seller, which notice sets forth in reasonable detail the nature of such material breach, provided that if such material breach is not reasonably capable of being remedied within the thirty (30) Day remedy period specified above but is reasonably capable of being remedied, Buyer shall have an additional sixty (60) Day remedy period to remedy such material breach, so long as Buyer promptly commences and thereafter diligently pursues such remedy;

 

  (c)

Buyer fails to establish or maintain the credit support as required by Clause 7.8 and such breach is not cured within ten (10) Working Days after written notice of such breach from Seller;

 

  (d)

Any representation or warranty made by Buyer in Clause 32.1 is not true in all material respects as of the date made and such inaccuracy is not cured within thirty (30) Days after Seller notifies Buyer of such inaccuracy, which notice sets forth in reasonable detail the nature of the inaccuracy;

 

  (e)

A Bankruptcy Event occurs with respect to Buyer; and

 

  (f)

Buyer assigns the Agreement, except as described in Clause 4.1.

If an Event of Default with respect to Buyer has occurred, Seller will have the right, but not the obligation, at any time when such Event of Default is continuing, to designate by notice to Buyer a date for terminating the Agreement that will be no earlier than thirty (30) Days after the notice is deemed delivered. Upon the date designated as the termination date by Seller as a result of an Event of Default of Buyer, Seller shall (i) terminate performance of its obligations under the Agreement; and (ii) invoice Buyer in connection with any obligations performed under the Agreement for which Seller has not received payment by Buyer.

 

28.3

Remedies

Upon any termination of the Agreement (including by Buyer under Clause 6.5(b) or Clause 29.1), Seller shall deliver to Buyer the portions of the Liquefaction Train System for which Seller has received payment and which have not been delivered to the Delivery Point. Except where exclusive and/or sole remedies are expressly provided herein, (a) remedies available to each Party under the Agreement are cumulative and (b) whether or not the Agreement is terminated in accordance with this Clause 28, each Party may assert any claims under the Agreement, at law or in equity against the other Party for damages incurred by such Party resulting from any breach of, or default under, the Agreement by the other Party; but the Parties agree that such remedies and claims for damages incurred by such Party resulting from any breach of, or default under, the Agreement by the other Party are always subject to the (i) limitations and exclusions of liability and (ii) dispute resolution provisions provided for in the Agreement; provided, further, that the Delivery

 

A-70


Delay Liquidated Damages Cap, Aggregate Delivery Delay Liquidated Damages Cap, the Aggregate Performance Delay Liquidated Damages Cap, the Performance Delay Liquidated Damages Cap, the Liquefaction Train System Performance Delay Liquidated Damages Cap, the Performance Liquidated Damages Cap and the Liquidated Damages Cap shall not be construed to limit either Party’s liability hereunder upon a termination of the Agreement. Each Party agrees that it has a duty to mitigate Costs and covenants that it will use commercially reasonable efforts to minimize any Costs, including termination Costs that it may incur as a result of the other Party’s performance or non-performance hereof. Neither the termination nor expiration of the Agreement will relieve either Party of: (i) any undischarged liability of such Party in respect of the period prior to such termination or expiration (including for unpaid amounts owing under the Agreement in respect of the period prior to such termination or expiration, including payments due as a result of events occurring prior to such termination or expiration); or (ii) any liability for breach by such Party of the Agreement.

 

29.

TERMINATION AND SUSPENSION

 

29.1

Termination by Buyer

Buyer may at any time terminate the Agreement for its convenience by giving Seller [***] written notice of termination, but subject to payment of the Termination Fees in accordance with Clause 29 .2. The Agreement shall terminate with effect from the date indicated in such notice.

 

29.2

Termination Fee

In the event of a termination by Buyer under Clause 29 .1, Buyer shall pay to Seller the applicable termination payment, as determined in accordance with Appendix B (Pricing; Payment Terms & Cancellation Schedule) (the “Termination Fee”), provided that under no circumstances shall the Termination Fee exceed the applicable maximum Termination Fee set forth in the table in Appendix B (Pricing; Payment Terms & Cancellation Schedule) (the “Maximum Termination Fee”). The Termination Fee, if any, shall be paid within thirty (30) Days from Seller’s invoice therefor. The Termination Fee, if any, shall be Seller’s sole and exclusive remedy and Buyer’s sole and exclusive liability for a termination of the Agreement by Buyer for Buyer’s convenience. Buyer and Seller agree that the Termination Fee represents an accurate, reasonable and conservative estimate of the actual level of damages Seller is likely to suffer in the event of such Termination.

 

29.3

Order to Suspend Execution of the Agreement

 

  (a)

Buyer may at any time, upon thirty (30) Days’ prior written notice, instruct Seller to suspend the performance of Seller’s obligations under the Agreement or any portion thereof for such time and in such manner as Buyer may reasonably consider necessary. Upon receiving any such notice of suspension, Seller shall: (i) properly protect and secure the Liquefaction Train System against any deterioration, loss or damage, as considered necessary or required by Buyer; (ii) place no further

 

A-71


  purchase orders or subcontracts for materials, services or facilities with respect to the suspended performance; (iii) promptly make every reasonable effort to obtain suspension, with terms satisfactory to Buyer of all subcontracts with all Subcontractors to the extent they related to the suspended performance; and (iv) take any other reasonable steps to minimize costs and expenses associated with such suspension.

 

  (b)

Any Costs reasonably incurred and properly documented by Seller (including, but not limited to, demobilization, remobilization, storage, preservation, inspection, related labor and any other costs due to such suspension) in giving effect to Buyer’s suspension instructions under this Clause 29.3, shall be borne and paid by Buyer, or, unless such suspension is (i) necessary by reason of a breach or Event of Default on the part of Seller or (ii) due to a Force Majeure Event.

 

  (c)

If Buyer is in breach of its obligation to timely pay undisputed amounts owed to Seller under the Agreement, Seller may suspend immediately upon written notice to Buyer, without penalty and without further proof or establishment of cause, the performance of Seller’s obligations until such undisputed payment is made by Buyer. Seller shall be entitled to request a Change Order for an equitable adjustment of the Project Schedule to the extent that such Seller suspension adversely affects the delivery of any Liquefaction Train in accordance with the Project Schedule. Any Costs reasonably incurred and properly documented by Seller in accordance with such suspension (including storage, demobilization and re-mobilization costs) shall be payable by Buyer within thirty (30) Days of receipt of Seller’s invoices, provided Seller shall exercise commercially reasonable efforts to mitigate and minimize such Costs.

 

29.4

Resumption of Works

At any time after a suspension under Clause 29.3, Buyer may give written notice to Seller to proceed with the delivery of the Liquefaction Trains and/or with the execution of all or part of the Agreement suspended under this Clause 29. Seller will be entitled to a Change Order to equitably adjust the Contract Price and the Project Schedule prior to resuming performance.

 

29.5

Prolonged Suspension

If the performance of Seller’s obligations under the Agreement or any portion thereof is suspended pursuant to Clause 29.3 and if notice to resume execution is not given by Buyer within [***], then Seller may serve notice in writing to Buyer requesting permission to proceed with the Agreement or the portion in regard to which progress is suspended. If such permission to proceed is not granted by Buyer within [***] of Buyer’s receipt of such notice, either Party may, by a further prior written notice to the other Party, elect to terminate the Agreement. Seller shall transfer or assign to Buyer, title in the part of the Liquefaction Train System for which payment has been received in full as of the date of any termination of the Agreement. This Clause 29.5 shall not apply if the suspension was (i) necessary by reason of some material default on the part of Seller or (ii) due to a Force Majeure Event.

 

A-72


30.

GENERAL CLAUSES

 

30.1

No Third Party Beneficiary

The Parties expressly agree that Owner shall be a third party beneficiary of the Agreement entitled, in its own name, in the name of Buyer or in the name of any assignee of Buyer to enforce the Agreement against Seller (subject to such enforcement being subject to all the limitations, exclusions, remedies and defenses provided to Seller under the Agreement). Except as provided in the foregoing sentence with respect to Owner and in Clause 18.8, Clause 19 .2 and Clause 19 .3 with respect to the Buyer Parties and the Seller Parties, the provisions of the Agreement are for the benefit of the Parties hereto and not for any other third party. The Agreement shall be binding upon and inure to the benefit of each of the Parties and their respective successors and permitted assigns.

 

30.2

Severability

Should a determination be made by a court of competent jurisdiction that any provision of the Agreement is illegal, invalid or otherwise unenforceable, the same shall not affect the other terms or provisions of the Agreement, but such provisions shall be deemed modified to the extent necessary in the court’s opinion to render such term or provision enforceable, and the rights and obligations of the Parties shall be construed and enforced accordingly, preserving to the fullest extent possible the intent and agreements of the Parties set forth herein.

 

30.3

Counterparts

The Agreement may be executed in one or more counterparts, each of which shall be deemed an original, but all of which taken together shall constitute one and the same instrument. Signatures may be delivered electronically or by facsimile, and such copies shall be treated as originals for all purposes.

 

30.4

Attorney Review

The Parties acknowledge that each Party and its attorney have reviewed the Agreement and that any rule of construction to the effect that any ambiguities are to be resolved against the drafting Party, or any similar rule operating against the drafter of an agreement, shall not be applicable to the construction or interpretation of the Agreement.

 

30.5

Time is of the Essence

Time is of the essence in the performance of the Agreement.

 

A-73


30.6

No Waiver

The waiver by a Party of a breach of any provision of the Agreement by the other Party shall not be construed as a waiver of any succeeding breach of the same or any other provision, nor shall any delay or omission on the part of a Party to exercise or avail itself of any right, power or privilege that it has, or may have, hereunder operate as a waiver of any right, power or privilege by such Party. Any consent or permission granted under the Agreement shall be effective only in the specific instance and for the specific purpose given.

 

30.7

Survival

Upon termination of the Agreement, the rights and obligations of the Parties hereunder shall terminate, except for: (i) provisions that are indicated herein as surviving and those provisions that by their nature are intended to survive; and (ii) rights and obligations accrued as of the date of termination and in connection therewith.

 

30.8

Relationship to First Phase

The Parties acknowledge and agree that the First LTS Purchase Order is an independent agreement between the Parties and, notwithstanding anything contained herein to the contrary, the Agreement shall not be construed to interpret or modify, or otherwise challenge the enforceability of or invalidate, the First LTS Purchase Order.

 

30.9

Financial Closing

Seller acknowledges that Buyer’s issuance of FNTP is conditioned upon, and shall immediately follow, Buyer’s final investment decision and Financial Closing for the Facility.

 

31.

HAZARDOUSMATERIALS

 

31.1

Hazardous Materials

Seller shall, and shall cause all of its Subcontractors to, comply with all applicable Laws relating to Hazardous Materials. If Seller is performing any of its obligations hereunder at the Site, Seller shall not, nor shall it permit any Subcontractor to, bring, introduce, use or release any Hazardous Material on or at the Site. Seller shall be responsible for the management, storage, disposal, removal, treatment and/or remediation of any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site. In addition, Seller shall not, and shall cause its Subcontractors to not, take any action or fail to take any action, that may disrupt, release or exacerbate, or render more costly the removal or remediation of, any Hazardous Materials existing on the Site prior to the date Seller commences the performance of its obligations hereunder on the Site. Seller shall indemnify, defend, release and hold harmless the Buyer Parties from any costs, expenses or liability resulting from any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site, to the extent resulting

 

A-74


from Seller’s or its Subcontractors’ fault, negligence (in any form) or willful misconduct. Buyer shall indemnify, defend, release and hold harmless the Seller Parties from any costs, expenses or liability resulting from any Hazardous Material use or releases on or at the Site, excluding any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site.

 

31.2

Notification

If Seller encounters a condition at the Site involving a Hazardous Material or if Seller or anyone for whom Seller is responsible creates a condition involving a Hazardous Material, Seller shall promptly: (a) secure or otherwise isolate such condition, (b) stop its performance of its obligation hereunder in connection with such condition and in any area affected thereby and not take any action that may disrupt, release or exacerbate any such condition, and ( c) verbally notify Buyer (and promptly thereafter confirm such notice of such condition in writing). Seller shall cooperate with and assist Buyer in making the Site available for the taking of necessary remedial steps.

 

32.

REPRESENTATIONS AND WARRANTIES

 

32.1

Buyer Representations and Warranties

Buyer hereby represents and warrants to Seller that as of the Effective Date: (a) Buyer is a limited liability company duly organized, validly existing and in good standing under the laws of its state of organization and has all requisite limited liability company power and authority to own and operate its properties and assets and to carry on its business as now conducted; (b) Buyer is duly qualified and is authorized to transact business and is in good standing as a foreign organization in each jurisdiction in which the failure so to qualify would have a material adverse effect on its ability to perform its obligations under the Agreement; ( c) all limited liability company action on its part and on the part of its officers, managers and/or members necessary for the authorization, execution and delivery of the Agreement and the performance by it of all of its obligations hereunder have been taken; ( d) it has obtained all governmental approvals or third party approvals required for the performance by it of its obligations under the Agreement; ( e) there is no action pending or, to its knowledge, currently threatened against it that seeks to prohibit the transactions contemplated by the Agreement or adversely affect its ability to perform under the Agreement; and (f) the Agreement constitutes the legal, valid and binding obligation of Buyer, enforceable in accordance with its terms (subject to principles of equity, the effect of bankruptcy, insolvency, reorganization, receivership, moratorium, and other similar laws), and the execution, delivery and performance of the Agreement by Buyer does not and will not, in any material respect, conflict with, violate or cause a breach of any applicable Law, material agreement, contract or instrument to which Buyer is a party or any judgment, order or decree to which Buyer is subject.

 

A-75


32.2

Seller Representations and Warranties

Seller hereby represents and warrants to Buyer that as of the Effective Date: (a) Seller is a limited liability company duly organized, validly existing and in good standing under the laws of its state of organization and has all requisite limited liability company power and authority to own and operate its properties and assets and to carry on its business as now conducted; (b) Seller is duly qualified and is authorized to transact business and is in good standing as a foreign organization in each jurisdiction in which the failure so to qualify would have a material adverse effect on its ability to perform its obligations under the Agreement; ( c) all limited liability company action on its part and on the part of its officers, managers and/or members necessary for the authorization, execution and delivery of the Agreement and the performance by it of all of its obligations hereunder have been taken; ( d) it has obtained all governmental approvals or third party approvals required for the performance by it of its obligations under the Agreement; (e) there is no action pending or, to its knowledge, currently threatened against it that seeks to prohibit the transactions contemplated by the Agreement or adversely affect its ability to perform under the Agreement; (f) the Agreement constitutes the legal, valid and binding obligation of Seller, enforceable in accordance with its terms (subject to principles of equity, the effect of bankruptcy, insolvency, reorganization, receivership, moratorium, and other similar laws), and the execution, delivery and performance of the Agreement by Seller does not and will not, in any material respect, conflict with, violate or cause a breach of any applicable Law, material agreement, contract or instrument to which Seller is a party or any judgment, order or decree to which Seller is subject.

 

33.

FORCE MAJEURE

 

33.1

Force Majeure Event

 

  (a)

Each Party shall not be liable or be considered to be in breach or default of its obligations under the Agreement to the extent that performance of such obligations is delayed or prevented, by a Force Majeure Event. A “Force Majeure Event” means any cause or event, or any combination of any causes or events, that: (i) is unforeseeable; (ii) is beyond the reasonable control and without fault or negligence of the affected Party; (iii) could not have been prevented in whole or in part by the exercise of reasonable care and skill by the affected Party; and (iv) materially impairs or prevents the performance of obligations under the Agreement by the affected Party. Subject to the requirements of the preceding sentence, Force Maj eure Events may include, but are not limited to, acts of God or the public enemy, acts ( or omissions) of Governmental Authorities, fires, severe weather conditions, earthquakes, strikes or other labor disturbances, floods, war ( declared or undeclared), armed conflict, acts or threats of terrorism, epidemics (including the pandemic known as COVID-19), civil unrest, riot, delays or interruptions of or by any Governmental Authority of the Country or of any other governments having jurisdiction, embargoes or quarantines. The Parties acknowledge that this Agreement reflects the impact of the COVID-19 epidemic as of the Effective Date. To the extent new adverse circumstances pertaining to the COVID-19 epidemic arise after the Effective Date, each Party shall continue to work in good faith to mitigate any resulting impact, and shall be entitled, if and to the extent applicable, to relief in accordance with this Clause 33.

 

A-76


  (b)

For the avoidance of doubt, a Force Majeure Event does not include (except and to the extent that they result directly from a Force Majeure Event), among others: (i) technical failures, normal wear and tear in machinery, or breakdown in equipment; (ii) shortage of parts, materials or other similar circumstances for which Seller may be responsible pursuant to the Agreement; (iii) late or non-delivery of machinery, equipment, materials or spare parts; (iv) a delay or default in the performance of any Subcontractor or supplier, or any other contractor; (v) strike or labor disturbances limited in scope to those solely affecting Seller or any of its Major Subcontractors; and (vi) changes since the date hereof in applicable Laws or their interpretation.

 

33.2

Force Majeure Relief

So long as the affected Party has at all times since the occurrence of the Force Majeure Event complied with the obligations of this Clause 33 and continues to so comply, then:

 

  (a)

the affected Party shall not be liable for any failure or delay in performing its obligations which are affected by the Force Majeure Event under or pursuant to the Agreement during the existence of a Force Majeure Event;

 

  (b)

each Party will bear its Cost caused by the circumstances of the Force Majeure Event; and

 

  (c)

in case of a Force Majeure Event affecting Seller, Buyer shall be released from its payment obligations under the Agreement, other than in respect of any amounts that became due and owing under the Agreement prior to the occurrence of the Force Majeure Event that are unpaid, for the duration of the Force Majeure Event.

If Seller claims a Force Majeure Event, Seller shall be entitled to request a Change Order pursuant to Clause 24, in order to obtain an equitable suspension of performance or extension of time (including an extension of the Project Schedule to the extent compliance thereof is affected) with respect thereto.

 

33.3

Notice of Force Majeure

If either Party considers that a Force Majeure Event has occurred which may affect performance of its obligations, it shall notify the other Party as soon as possible but within a maximum often (10) Days from the Force Majeure Event occurrence date (or from the date it became aware of the occurrence) giving written particulars of the relevant event and its effect upon its performance under the Agreement and, where known, the expected duration of the failure to perform. If the Party declaring a Force Majeure Event does not notify the other Party within such ten (10) Day period, then any relief provided to the declaring Party under this Clause 33 shall only be available as of the date that such notice

 

A-77


was provided to the other Party. As soon as the Force Majeure Event has ended, the Party claiming such Force Majeure Event shall give written notice to the other Party of the precise date of the end of the Force Majeure Event and the extent, with justification, to which it has actually been affected in the performance of its obligations.

 

33.4

Force Majeure Report

Upon the occurrence of any Force Majeure Event, Seller shall use its best efforts to continue to perform its obligations under the Agreement and to minimize the adverse effects of such Force Majeure Event. Seller shall notify Buyer of the steps it proposes to take including any reasonable alternative means to continue the performance of its obligations under the Agreement. Seller shall not take any such steps unless approved by Buyer. In the case of Seller declaring a Force Majeure Event, within twelve (12) Days after giving such notice Seller shall prepare and deliver to Buyer an appraisal report of the effects of the Force Majeure Event (the “Force Majeure Report”). The Force Majeure Report shall:

 

  (a)

specify the Force Majeure Event;

 

  (b)

describe the damage to and/or other effects on the Liquefaction Train System resulting from the Force Majeure Event; and,

 

  (c)

provide a good faith estimate (in each case to the extent applicable m the circumstances) of:

 

  (i)

the time it will take to restore such condition;

 

  (ii)

the effect which the relevant Force Majeure Event is likely to have upon any other contract relating to the Agreement;

 

  (iii)

whether or not, in Seller’s opinion, the completion or continued manufacturing of the Liquefaction Train System is technically viable with the reasons for such opinion; and

 

  (iv)

include all relevant supporting documentation.

In addition to the Force Majeure Report, Buyer may request, and Seller shall promptly provide, such related information pertaining to the Force Majeure Report as may be reasonable.

 

33.5

Termination for Force Majeure

If circumstances or consequences of a Force Majeure Event have occurred and shall continue for an uninterrupted period of [***] after date of occurrence then, notwithstanding that Seller may by reason thereof have been granted an extension of the Delivery Date, the non-claiming Party shall be entitled to serve upon the Party affected by the Force Majeure Event an additional fifteen (15) Days’ notice to terminate the Agreement. If, at the expiry of such

 

A-78


period, the Force Majeure Event is still in effect, the Agreement shall terminate. In the event of a termination of the Agreement due to a Force Majeure Event, the following provisions shall apply:

 

  (a)

neither Party shall have any liability to the other in respect of termination of the Agreement due to a Force Majeure Event, but rights and liabilities which have accrued prior to termination shall survive;

 

  (b)

upon such termination, Seller shall transfer or assign to Buyer, title in the part of the Liquefaction Train System for which payment has been received in full as of the date of the termination of the Agreement under this Clause 33.5; and

 

  (c)

upon such termination, Buyer shall pay to Seller any unpaid amounts due Seller for Payment Milestones completed as of the date of termination.

 

34.

LIMITED RECOURSE

 

  (a)

Excepting to the extent as otherwise provided in any parent guarantee provided to Seller under the Agreement, in the event of non-performance by Buyer of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (i) any assets or properties of any of the shareholders, members or partners of the Buyer, (ii) any Affiliate of Buyer or (iii) any officers, directors or employees thereof, and no judgment relating to the obligations of Buyer under the Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of Buyer or any other officer, employee or director past, present or future of Buyer or any of its shareholders, members, partners or Affiliates.

 

  (b)

Excepting to the extent otherwise provided in any parent guarantee provided to Buyer under the Agreement, in the event of non-performance by Seller of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (i) any assets or properties of any of the shareholders, members or partners of the Seller, (ii) any Affiliate of Seller or (iii) any officers, directors or employees thereof, and no judgment relating to the obligations of Seller under the Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of the Seller or any other officer, employee or director past, present or future of the Seller or any of its shareholders, members, partners or Affiliates.

 

A-79


APPENDIX B

PRICING; PAYMENT TERMS & CANCELLATION SCHEDULE

See attached.

 

B-1


APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one (1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement.

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders.

In addition to the amounts shown in the Payment Milestone in Section LB., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] during the first [***] of the Payment Schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the transportation fixed fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of [***]. In all other cases, Facility-specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Plaquemines Parish sales and use taxes that constitute Buyer Taxes. Any such Plaquemines Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.

 

B-2


I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of LNTP shall be as indicated in the table below.

 

Type

  

Milestone

No

  

Payment Milestone Description

  

Amount

(USD)

[***]

   1    [***]    [***]

[***]

   L1    [***]    [***]

[***]

   2    [***]    [***]

[***]

   3    [***]    [***]

 

B-3


  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   1    [***]    [***]

[***]

   L1    [***]    [***]

[***]

   2    [***]    [***]

[***]

   3    [***]    [***]

 

B-4


Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   4    [***]    [***]

[***]

   5    [***]    [***]

[***]

   6    [***]    [***]

[***]

   7    [***]    [***]

[***]

   8    [***]    [***]

[***]

   9    [***]    [***]

[***]

   10    [***]    [***]

[***]

   11    [***]    [***]

[***]

   12    [***]    [***]

[***]

   13    [***]    [***]

[***]

   14    [***]    [***]

[***]

   15    [***]    [***]

[***]

   16    [***]    [***]

 

B-5


Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   17    [***]    [***]

[***]

   18    [***]    [***]

[***]

   19    [***]    [***]

[***]

   20    [***]    [***]

[***]

   21    [***]    [***]

[***]

   22    [***]    [***]

[***]

   23    [***]    [***]

[***]

   24    [***]    [***]

[***]

   25    [***]    [***]

[***]

   26    [***]    [***]

 

Payment Milestone Notes

1

   [***]

2

   [***]

3

   [***]

4

   [***]

5

   [***]

6

   [***]

 

B-6


Payment Milestone Notes

7

   [***]

8

   [***]

9

   [***]

10

   [***]

11

   [***]

12

   [***]

 

B-7


II.

Aggregate Payment Milestone Cap:

The aggregate amount of all Payment Milestones invoiced by Seller as of each month, including all invoices submitted to Buyer in prior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month.

 

  A.

[***].

 

Month after Issuance of LNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

  A.

[***]

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-8


Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-9


Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-10


III.

Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29 .1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]

where:

[***]

 

Months after issuance of LNTP or
issuance of a Suspension Notice, as
Applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-11


4.

If LNTP is issued and FNTP is subsequently issued prior to the termination of the Agreement, the Maximum Termination Fee shall be as follows; provided, however, that if (a) no LNTP is issued but the FNTP is issued or (b) FNTP is issued less than [***] after the issuance of LNTP, in either case, the Maximum Termination Fee set forth in the first [***] in the table below shall be increased by [***].

 

Months after issuance of LNTP or FNTP or
issuance of a Suspension

Notice, as applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-12


Months after issuance of LNTP or
FNTP or issuance of a Suspension
Notice, as applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-13


APPENDIX C

SCOPE OF SUPPLY & PROJECT SCHEDULE

[Omitted]

 

C-1


APPENDIX D

FORM OF BUYER PARENT COMPANY GUARANTEE

[Omitted]

 

D-1


APPENDIX E

QUALITY ASSURANCE AND QUALITY CONTROL

[Omitted]

 

E-1


APPENDIX F

PERFORMANCE TESTS

[Omitted]

 

F-1


APPENDIX G

APPROVED SUBCONTRACTORS

[Omitted]

 

G-1


APPENDIX H

FORM OF SELLER PARENT COMPANY GUARANTEE

[Omitted]

 

H-1


APPENDIX I

FORM OF CHANGE ORDER

[Omitted]

 

I-1


APPENDIX J

FORM OF LIEN WAIVERS AND RELEASES

[Omitted]

 

J-1


APPENDIX K

PHYSICAL TRANSPORTATION COSTS

At least six (6) months prior to the delivery of the first Liquefaction Train under the Agreement, Seller shall provide to Buyer for Buyer’s review and approval, such approval not to be unreasonably withheld, conditioned or delayed, a plan for the delivery of the Liquefaction Trains in accordance with the delivery schedule, including the identity of the transportation vendors and the estimated Transportation Costs for the Agreement.


APPENDIX L

LIQUIDATED DAMAGE AMOUNTS

 

I.

Delivery Delay Liquidated Damages (Clause 6.4(c)(i)(1)):

 

Day

  

Liquidated Damage

Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

L-1


II.

Delivery Delay Liquidated Damages (Clause 6.4(c)(ii)(1)):

 

Day

  

Liquidated Damage

Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

L-2


III.

Performance Delay Liquidated Damages (Clause 25.3(b)(i)(x)(1)):

 

Day

  

Liquidated Damage

Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

L-3


IV.

Performance Delay Liquidated Damages (Clause 25.3(b)(i)(y)(1)):

 

Day

  

Liquidated Damage

Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

L-4


I.

Performance Delay Liquidated Damages (Clause 25.3(b)(ii)(1)):

 

Day

  

Liquidated Damage

Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

L-5


APPENDIX M

CONTRACT PRICE ADJUSTMENTS

Part 1

The Contract Price shall be adjusted by the following adjustment index formula, provided that such adjustment shall (a) not be subject to any compounding and (b) be limited to a maximum reduction of [***], and maximum increase of [***] per annum:

[***]

where:

 

   

P1 = Calculated escalated Contract Price

 

   

PO = Original Contract Price

 

   

Index 1 = applicable index for the month of issuance of LNTP, or FNTP if LNTP is not issued,

 

   

Index 0 = applicable base index for the month of the Effective Date

and:

[***]

 

M-1


Part 2

The Contract Price shall be adjusted for foreign exchange as follows:

 

(i)

An amount in US Dollars equal to [***] of the Contract Price shall be converted from US Dollars into Euro at the exchange rate for US Dollars to Euro as of the Effective Date, which is stipulated to be [***] US Dollars to [***] Euro.

 

(ii)

The Euro amount determined pursuant to clause (i) shall be re-converted to US Dollars on the day of issuance of LNTP, or FNTP if LNTP is not issued, using the Euro reference exchange rate for the US Dollar published by the European Central Bank at link https://www.ecb.europa.eu/stats/policy_and_exchange_rates/euro_reference_exchange_rates/ html/index.en.html as determined by the Parties.

 

(iii)

An amount in US Dollars equal to [***] of the Contract Price shall be subtracted from the re-converted US Dollar amount determined pursuant to clause (iii).

 

(iv)

If the amount determined pursuant to clause (iii) is positive, it shall be added to the Contract Price by Change Order. If the amount determined pursuant to clause (iii) is negative, it shall be deducted from the Contract Price by Change Order.

 

M-2


Part 3

The Contract Price shall be further adjusted by the following adjustment index formula, provided that such adjustment shall (a) not be subject to any compounding and (b) be limited to a maximum reduction of [***], and maximum increase of [***] per annum:

[***]

where:

 

   

P1 = Calculated escalated Contract Price

 

   

PO = Original Contract Price for LTS Purchase Order

 

   

Index 1 = applicable index for the month of issuance of FNTP

 

   

Index 0 = applicable base index for the month that is [***] months after issuance of LNTP

and:

[***]

 

M-3


If the amount determined pursuant to this Part 3 is positive, it shall be added to the Contract Price by Change Order. If the amount determined pursuant to this Part 3 is negative, no amount shall be deducted from the Contract Price.

Part 4

The Contract Price shall be adjusted for foreign exchange as follows:

 

(i)

An amount in US Dollars equal to [***] of the Contract Price shall be converted from US Dollars into Euro at the exchange rate for US Dollars to Euro as of the LNTP issuance date.

 

(ii)

The Euro amount determined pursuant to clause (i) shall be re-converted to US Dollars on the day of issuance of FNTP, using the Euro reference exchange rate for the US Dollar published by the European Central Bank at link https://www.ecb.europa.eu/stats/policy_and_exchange_rates/euro_reference_exchange_rates/ html/index.en.html as determined by the Parties.

 

(iii)

An amount in US Dollars equal to [***] of the Contract Price shall be subtracted from the re-converted US Dollar amount determined pursuant to clause (iii).

 

(iv)

If the amount determined pursuant to clause (iii) is positive, it shall be added to the Contract Price by Change Order. If the amount determined pursuant to clause (iii) is negative, no amount shall be deducted from the Contract Price by Change Order.

 

M-4

Exhibit 10.41

GUARANTY AGREEMENT

THIS GUARANTY AGREEMENT (this “Guaranty”) is made as of the 5th day of August, 2022, by Baker Hughes Holdings LLC, a limited liability company duly organized and existing under the laws of the State of Delaware, with its primary office at 17021 Aldine Westfield Road, Houston, Texas 77073 (herein called “Guarantor”), for the benefit of Venture Global Plaquemines LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware, with its primary office at 1001 19th Street North, Suite 1500, Arlington, Virginia 22209 (herein called “Buyer”). Guarantor and Buyer are individually referred to herein as a “Party” and collectively as the “Parties.”

RECITALS:

WHEREAS, Baker Hughes Energy Services LLC, a limited liability company organized and existing under the laws of the State of Delaware, with a place of business at 17021 Aldine Westfield Road, Houston, Texas 77073 (herein called “Seller”) is an affiliate of Guarantor;

WHEREAS, Buyer and Seller have entered into a Purchase Order Contract for the Sale of Liquefaction Train System dated as of August 5, 2022 (together with the schedules, annexes, and exhibits thereto and as the same may be amended from time to time, herein called the “Contract”), for the supply of certain natural gas liquefaction equipment by Seller;

WHEREAS, the Contract requires Guarantor to guarantee Seller’s performance under the Contract for the benefit of Buyer; and

WHEREAS, Guarantor indirectly owns the majority of the membership interests of Seller and, as ultimate parent company of Seller, is willing to enter into this Guaranty in satisfaction of the conditions of the Contract.

NOW, THEREFORE, in consideration of the premises and mutual covenants set forth herein, the Parties hereto agree as follows:

1. Subject to Section 2, Guarantor unconditionally, absolutely and irrevocably guarantees to Buyer, and its successors and assigns, as and for its own obligation, and not as a surety, that in the event of Seller failing in any respect to perform or observe any obligation owed by Seller to Buyer, whether now existing or hereafter arising, under the terms and provisions of the Contract, Guarantor shall within ten (10) Working Days (as such term is defined in the Contract) upon first demand in writing by Buyer (a) perform or take such steps as are necessary to achieve performance or observance of such obligations and (b) indemnify, defend and hold harmless the Buyer Parties (as such term is defined in the Contract) against any and all losses, damages, claims, costs, charges, and expenses, howsoever arising, from the said failure to the extent of Seller’s liability under the Contract.

2. Notwithstanding anything to the contrary contained in this Guaranty or the Contract, the Guarantor’s aggregate liability under this Guaranty at any time prior to the issuance of FNTP shall not exceed the applicable Maximum Termination Fee.

 

L-1


3. This Guaranty constitutes an independent guaranty, and is not conditioned on or contingent upon or modified, impaired or prejudiced by: (a) any attempt to enforce in whole or in part any obligations of Seller to Buyer; (b) the existence or continuance of Seller as a legal entity; (c) the consolidation or merger of Seller with or into any other entity; (d) the sale, lease or disposition by Seller of all or substantially all of its assets to any other entity; (e) the bankruptcy or insolvency of Seller or the making by Seller of a general assignment for the benefit of creditors; (f) any other security now or hereafter held by Buyer as security for the obligations of Seller; (g) the compromise, settlement, release, waiver, change, modification, or termination of any of Seller’s obligations under the Contract; (h) the extension of time for payment of any amounts due from Seller or of the time for performance of any of Seller’s obligations under the Contract; or (i) the failure, omission, delay or lack on the part of Buyer to enforce or exercise any right, power or remedy under or pursuant to the terms of the Contract or this Guaranty.

4. Guarantor’s payment and performance shall be subject to the defenses and the limits on Seller’s liability under the Contract. Guarantor agrees to make any payment due hereunder upon first written demand, without set-off or counterclaim and without any legal formality, such as protest or notice being necessary, and waives all privileges or rights which it may have as a guarantor, including (a) any right to require Buyer to claim payment or to exhaust remedies against Seller or any other person, (b) notice of any fact which might substantially increase Buyer’s risk; (c) notice of presentment for payment, demand or protest and notice thereof as to any instrument; (d) notice of Seller’s default; (e) any defense arising by reason of any incapacity, lack of authority or disability; (f) any defense arising because of the exercise of any right or remedy available to, or election made by, Buyer pursuant to the U.S. Bankruptcy Code and (g) all other notices and demands to which Guarantor might otherwise be entitled.

5. The obligations of Guarantor hereunder are primary and original obligations and shall continue in full force and effect after expiry or termination of the Contract until all of Seller’s obligations and liabilities under the Contract have been fully discharged, without regard to future changes in conditions, including change in law or any invalidity or irregularity with respect to the execution and delivery of this Guaranty.

6. Guarantor irrevocably and absolutely waives any and all rights of subrogation, contribution, indemnification, reimbursement or similar rights against Seller with respect to this Guaranty. In addition, Guarantor will not exercise any rights which it may acquire by way of subrogation under this Guaranty by any payment made hereunder or otherwise, until all of Seller’s obligations owed to Buyer shall have indefeasibly been performed or paid in full.

7. This Guaranty shall continue to be effective or be reinstated, as the case may be, if at any time any payment by Guarantor or Seller to Buyer is annulled, set aside, invalidated, declared to be fraudulent or preferential, rescinded or must otherwise be returned, refunded or repaid by Buyer upon the insolvency, bankruptcy, reorganization, dissolution or liquidation of Seller, Guarantor or otherwise, and is so rescinded or returned to the party or parties making such payment, all as though such payment had not been made.

 

L-2


8. This Guaranty and the undertakings herein contained shall be binding upon the successors and assigns of Guarantor and shall extend to and inure for the benefit of the successors or permitted assignees of Buyer. Guarantor may not assign its rights and obligations hereunder or assign or otherwise transfer this Guaranty or any interest herein, without the prior written consent of Buyer. Buyer may assign or transfer all or any of its right, title and interest in this Guaranty in connection with any assignment of the Contract in accordance with the requirements specified therein, including a collateral assignment to Lenders (as such term is defined in the Contract). No person other than Buyer or such permitted assignees or transferees as described above is intended as a beneficiary of this Guaranty nor shall any such person have any rights hereunder.

9. No assignment or transfer of the Contract or this Guaranty shall operate to extinguish or diminish the liability of Guarantor hereunder.

10. This Guaranty shall terminate and shall no longer be of any force or effect, and shall promptly be returned by Buyer to Guarantor, upon the earlier to occur of (a) the performance by Seller of all of its obligations under the Contract or (b) the delivery by Seller of replacement credit support pursuant to and in accordance with the Contract.

11. In the event there is any dispute under the Contract that relates to a sum being claimed under this Guaranty, which dispute is submitted to arbitration in accordance with the Contract, the obligations under this Guaranty with respect to such sum being claimed shall be suspended pending the outcome of such arbitration and Guarantor further agrees that any award resulting from such arbitration shall be conclusive and binding on it for purposes of determining its obligation under this Guaranty.

12. Guarantor represents and warrants to Buyer that: (a) Guarantor is a limited liability company duly formed, validly existing and in good standing under the laws of its jurisdiction of formation; (b) the execution, delivery and performance by Guarantor of this Guaranty have been duly authorized by all necessary actions on the part of Guarantor; and (c) this Guaranty constitutes a legally binding obligation of Guarantor, except as the enforceability hereof may be limited by applicable bankruptcy, insolvency, moratorium and other laws affecting Buyer’s rights generally and by equitable principles (regardless of whether enforcement is sought in equity or at law).

13. Subject to Section 2, Guarantor agrees to pay all expenses (including court costs and reasonable attorney’s fees) incurred by Buyer in connection with defending and enforcing its rights under this Guaranty.

14. This Guaranty shall be governed by and construed in accordance with the laws of the State of New York, excluding only those provisions regarding conflict of laws.

15. The Parties irrevocably waive any objections, which they may have now or hereafter to (a) the personal or subject matter jurisdiction of the federal or state courts located in the State of New York, (b) the venue of any proceedings brought in the federal or state courts located in the State of New York, or (c) that such proceedings have been brought in a non-convenient forum. The Parties irrevocably agree that any final judgment (after appeal or expiration of time for appeal) entered by any such courts shall be conclusive and binding upon the Parties and may be enforced in the courts or any other jurisdiction to the fullest extent permitted by applicable law.

[Signature page follows]

 

L-3


IN WITNESS WHEREOF, the Parties hereto have caused this Guaranty to be executed by their respective authorized representatives as of the date first written above.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC   BAKER HUGHES HOLDINGS LLC
By:  

/s/ Jonathan W. Thayer

  By:  

/s/ Steven Krippner

Name:  

Jonathan W. Thayer

  Name:  

Steven Krippner

Title:  

Chief Financial Officer

  Title:  

Vice President, Treasurer

 

L-4

Exhibit 10.42

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

CHANGE ORDER NO. 01

UNDER THE PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

April 7, 2023

Reference is made to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of August 5, 2022 (as amended, the “Agreement”), by and between Venture Global Plaquemines LNG, LLC, a Delaware limited liability company (“Buyer”) and Baker Hughes Energy Services LLC, a Delaware limited liability company (“Seller”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. Except to the extent as may be specifically described in this Change Order, the changes set forth herein do not relieve Seller of any of its responsibilities described in the Agreement.

Once this Change Order is executed by both Parties, and except to the extent set forth herein, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Seller fully for all such effects.

Buyer and Seller agree to the following changes to the Agreement:

EARLY DELIVERY BONUS

 

  1.

The following defined terms shall be inserted in Clause 1.1 of Appendix A to the Agreement in alphabetical order:

““Bonus Date” has the meaning given to it in Clause 6.7.

Bonus Degradation Factor” has the meaning given to it in Clause 6.7.

E-House ” means the building in common between two (2) Liquefaction Trains containing the necessary electrical and control panels to operate the system.”

Super Bonus Date” has the meaning given to it in Clause 6.7.

Super Bonus Degradation Factor” has the meaning given to it in Clause 6.7.”

 

  2.

Appendix A to the Agreement is hereby amended by deleting Clause 6.7 in its entirety and inserting the following in its place:

“6.7 Delivery Bonus

If Seller delivers a Liquefaction Train to Buyer at the Delivery Point, and its associated E-House is ready for shipment at Seller’s Subcontractor fabrication site located in [***], in each case on or before the applicable bonus date set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (each, a “Bonus Date”) for such Liquefaction Train and associated E-


Execution Version

 

House, then Buyer shall pay to Seller the applicable bonus amount set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) for such Liquefaction Train and associated E-House. If Seller delivers a Liquefaction Train, and its associated E-House is ready for shipment at Seller’s Subcontractor fabrication site located in [***], before the applicable Delivery Date but after the applicable Bonus Date, the amount payable to Seller in respect of such Liquefaction Train and associated E-House shall be reduced by an amount equal to the applicable bonus degradation factor set forth Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (in each case, the “Bonus Degradation Factor”) multiplied by the number of days from the Bonus Date to the average of the actual date of delivery of such Liquefaction Train to the Delivery Point and the actual date of readiness for shipment of such associated E-House at Seller’s Subcontractor fabrication site located in [***]. Each of such bonus amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement.

In addition to any bonus due pursuant to the preceding paragraph, if Seller delivers a Liquefaction Train to Buyer at the Delivery Point, and each of its associated E-House and Cold Box is ready for shipment at Seller’s Subcontractors fabrication sites located in [***] and [***], respectively, in each case on or before the applicable super bonus date set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (each, a “Super Bonus Date”) for such Liquefaction Train and associated E-House and Cold Box, then Buyer shall pay to Seller the applicable super bonus amount set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) for such Liquefaction Train and associated E-House and Cold Box. If Seller delivers a Liquefaction Train, and each of its associated E-House and Cold Box is ready for shipment at Seller’s Subcontractors fabrication sites located in [***] and [***], respectively, before the applicable Delivery Date but after the applicable Super Bonus Date, the amount payable to Seller in respect of such Liquefaction Train and associated E-House and Cold Box shall be reduced by an amount equal to the applicable super bonus degradation factor set forth Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (in each case, the “Super Bonus Degradation Factor”) multiplied by the number of days from the Super Bonus Date to the average of the actual date of delivery of such Liquefaction Train to the Delivery Point, the actual date of readiness for shipment of the E-House at Seller’s Subcontractor fabrication site located in [***] and the actual date of readiness for shipment of the Cold Box at Seller’s Subcontractor fabrication site located in [***]. Each of such super bonus amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement.

If any of the Liquefaction Trains, associated E-Houses or associated Cold Boxes is not delivered to the Delivery Point in its entirety on or before the applicable Delivery Date, then no bonus amount shall be earned or due.

For the purposes of this Clause 6.7 only, Seller shall be deemed to have delivered any Liquefaction Train, or have each of its associated E-House and Cold Box ready for shipment, as described in this Clause 6.7, on or before the Bonus Date and/or the Super Bonus Date, as applicable, notwithstanding that certain minor items forming a part of such Liquefaction Train or associated E-House or Cold Box have not been delivered to Buyer at the Delivery Point by such Bonus Date or Super Bonus Date; provided that (i) the Lender’s Engineer has confirmed to Buyer in writing (upon Buyer’s request) that the absence of such minor items would not reasonably be expected to adversely impact the project schedule for testing, commissioning, safety or operability of such Liquefaction Train,E-House or Cold Box, and (ii) all such minor items are delivered to Buyer at the Delivery Point not later than the relevant Delivery Date for such Liquefaction Train, E-House or Cold Box in the Project Schedule or such other date as mutually agreed by the Parties in writing.


Execution Version

 

Amounts earned by Seller pursuant to this Clause 6.7 shall be due and payable by Buyer to Seller upon completion of delivery by Seller of the Liquefaction Train System and all Components (as such term is defined in the PIS Purchase Order) of the power island system in accordance with the PIS Purchase Order and the finalization of a Change Order within [***] thereof.”

PROJECT SCHEDULE

Attached as Exhibit A to this Change Order is a revised version of Annex C-1 (Project Schedule) of Appendix C (Scope of Supply & Project Schedule), which supersedes and replaces the existing Annex C-1 (Project Schedule) in its entirety.

CONTRACT PRICE

This Change Order has no impact on the Contract Price.

All other terms and conditions of the Agreement remain unchanged and in effect unless specifically modified herein.

Seller waives any and all rights to claim any payment or any relief for time for the performance of its obligations for the performance of the scope of the changes that are set forth under this Change Order. This Change Order constitutes compensation in full for Seller for all costs and expenses directly or indirectly attributable to the changes set forth herein, for all delays related thereto, and for performance of the changes within the time stated. Notwithstanding, such adjusted Contract Price does not include any Buyer Taxes which will be added to such Contract Price in accordance with and subject to the terms of the Agreement.

All other terms and conditions of the Agreement remain in effect unless specifically modified herein.

[Signature Page Follows.]


Agreed pursuant to the Agreement by:    
Baker Hughes Energy Services LLC     Venture Global Plaquemines LNG, LLC
By:  

/s/ Marco Caccavale

    By:  

/s/ Keith Larson

Name:   Marco Caccavale     Name:   Keith Larson
Title:   President     Title:   Secretary


Execution Version

 

Exhibit A

Annex C-1

LTS Project Schedule

[Omitted]

Exhibit 10.43

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution version

CHANGE ORDER NO. 02

UNDER THE PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

May 24, 2023

Reference is made to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of August 5, 2022 (as amended, the “Agreement”), by and between Venture Global Plaquemines LNG, LLC, a Delaware limited liability company (“Buyer”) and Baker Hughes Energy Services LLC, a Delaware limited liability company (“Seller”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, including any adjustment to the Contract Price and/or the Project Schedule set forth herein, as applicable, has been agreed upon by the Parties in accordance with Clause 24 of Appendix A (General Terms & Conditions) of the Agreement, and is considered an amendment to the Agreement. Except to the extent as may be specifically described in this Change Order, the changes set forth herein do not relieve Seller of any of its responsibilities described in the Agreement.

Once this Change Order is executed by both Parties, and except to the extent set forth herein, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Seller fully for all such effects.

SCOPE:

This Change Order modifies the Payment Milestones. Attached as Exhibit A to this Change Order is a revised version of Appendix B (Pricing; Payment Terms & Cancellation Schedule), which supersedes and replaces the existing Appendix B (Pricing; Payment Terms & Cancellation Schedule) in its entirety.

This Change Order also modifies Appendix C (Scope of Supply & Project Schedule) as set forth below:

 

  1.

Section 1.2.1 (Feed Gas Liquefaction) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet points immediately after the last sentence of the Cold Box Equipment section:

[***]


Execution version

 

  2.

Section 1.2.2 (Mixed Refrigerant) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet point immediately after the last bullet point in the subsection entitled, “Lube Oil System”:

[***]

 

  3.

MR Compressor String Test Scope Removal credit

[***]

 

  4.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting two new bullet points immediately after the last sentence in the subsection entitled, “Others”:

[***]

 

  5.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last sentence in the subsection entitled, “Utilities”:

[***]


Execution version

 

  6.

Section 1.2.2 (Mixed Refrigerant) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet points immediately after the last sentence of the section:

[***]


Execution version

 

  7.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following two new bullet points immediately after the last bullet point of the subsection “Others”:

[***]

 

  8.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a two new bullet points immediately after the last sentence in the subsection titled “Instrumentation & Control”:

[***]


Execution version

 

  9.

Section 1.2.2 (Mixed Refrigerant) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last bullet point in the subsection entitled, “Air-Cooled Heat Exchangers (mounted on Modules)”:

[***]

 

  10.

Section 1.3 (Electrical System Scope) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet point immediately after the last bullet point of the section:

[***]

 

  11.

Section 1.10 (Equipment and Components Preservation) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet point immediately after the last paragraph:

[***]


Execution version

 

  12.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet points immediately after the last paragraph:

[***]


Execution version

 

  13.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last sentence in the subsection entitled, “Structures and accessories”:

[***]


Execution version

 

  14.

Appendix A to the Agreement is hereby amended by deleting Clause 6.7 in its entirety and inserting the following in its place:

“6.7 Delivery Bonus

If Seller delivers a Liquefaction Train to Buyer at the Delivery Point, and its associated E- House is ready for shipment at Seller’s Subcontractor fabrication site located in [***], in each case on or before the applicable bonus date set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (each, a “Bonus Date”) for such Liquefaction Train and associated E-House, then Buyer shall pay to Seller the applicable bonus amount set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) for such Liquefaction Train and associated E-House. If Seller delivers a Liquefaction Train, and its associated E-House is ready for shipment at Seller’s Subcontractor fabrication site located in [***], before the applicable Delivery Date but after the applicable Bonus Date, the amount payable to Seller in respect of such Liquefaction Train and associated E-House shall be reduced by an amount equal to the applicable bonus degradation factor set forth Annex C-1 of Appendix C (Scope of Supply & Project


Execution version

 

Schedule) (in each case, the “Bonus Degradation Factor”) multiplied by the number of days after the Bonus Date to the average of the actual date of delivery of such Liquefaction Train to the Delivery Point and the actual date of readiness for shipment of such associated E- House at Seller’s Subcontractor fabrication site located in [***]. Each of such bonus amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement.

In addition to any bonus due pursuant to the preceding paragraph, if Seller delivers a Liquefaction Train to Buyer at the Delivery Point, and each of its associated E-House and Cold Box is ready for shipment at Seller’s Subcontractors fabrication sites located in [***] and [***], respectively, in each case on or before the applicable super bonus date set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (each, a “Super Bonus Date”) for such Liquefaction Train and associated E-House and Cold Box, then Buyer shall pay to Seller the applicable super bonus amount set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) for such Liquefaction Train and associated E-House and Cold Box. If Seller delivers a Liquefaction Train, and each of its associated E-House and Cold Box is ready for shipment at Seller’s Subcontractors fabrication sites located in [***] and [***], respectively, before the applicable Delivery Date but after the applicable Super Bonus Date, the amount payable to Seller in respect of such Liquefaction Train and associated E- House and Cold Box shall be reduced by an amount equal to the applicable super bonus degradation factor set forth Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (in each case, the “Super Bonus Degradation Factor”) multiplied by the number of days after the Super Bonus Date to the average of the actual date of delivery of such Liquefaction Train to the Delivery Point, the actual date of readiness for shipment of the E-House at Seller’s Subcontractor fabrication site located in [***] and the actual date of readiness for shipment of the Cold Box at Seller’s Subcontractor fabrication site located in [***]. Each of such super bonus amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement.

If any of the Liquefaction Trains, associated E-Houses or associated Cold Boxes is not delivered to the Delivery Point in its entirety on or before the applicable Delivery Date, then no bonus amount shall be earned or due.

For the purposes of this Clause 6.7 only, Seller shall be deemed to have delivered any Liquefaction Train, or have each of its associated E-House and Cold Box ready for shipment, as described in this Clause 6.7, on or before the Bonus Date and/or the Super Bonus Date, as applicable, notwithstanding that certain minor items forming a part of such Liquefaction Train or associated E-House or Cold Box have not been delivered to Buyer at the Delivery Point by such Bonus Date or Super Bonus Date; provided that (i) the Lender’s Engineer has confirmed to Buyer in writing (upon Buyer’s request) that the absence of such minor items would not reasonably be expected to adversely impact the project schedule for testing, commissioning, safety or operability of such Liquefaction Train, E-House or Cold Box, and (ii) all such minor items are delivered to Buyer at the Delivery Point not later than the relevant Delivery Date for such Liquefaction Train, E- House or Cold Box in the Project Schedule or such other date as mutually agreed by the Parties in writing.


Execution version

 

Amounts earned by Seller pursuant to this Clause 6.7 shall be due and payable by Buyer to Seller upon completion of delivery by Seller of the Liquefaction Train System and all Components (as such term is defined in the PIS Purchase Order) of the power island system in accordance with the PIS Purchase Order and the finalization of a Change Order within sixty (60) days thereof.”


Execution version

 

CONTRACT PRICE:

 

The original Contract Price was:

   $ [***]  

The net adjustment to the Contract Price by previously executed Change Orders is:

   $ [***]  

The Contract Price prior to this Change Order was:

   $ [***]  

The Contract Price shall be increased by this Change Order in the amount (the “Change Order Price”) of:

   $ [***]  
(comprised of: (a) a fixed lump sum amount of [***] with respect to the change set forth in clause (1) above (PCO# PLQ2 061B); (b) a fixed lump sum amount of [***] with respect to the change set forth in clause (2) above (PCO#64); (c) a negative fixed lump sum amount of [***] with respect to the change set forth in clause (3) above (PCO #65); (d) a fixed lump sum amount of [***] with respect to the change set forth in clause (4) above (PCO #66); (e) a fixed lump sum amount of [***] with respect to the change set forth in clause (4) above (PCO#67); (f) a fixed lump sum amount of [***] with respect of the change set forth above in clause (5) above (PCO#68); (g) a fixed lump sum of [***] with respect to the change set forth in clause (6) above (PCO#78); (h) a fixed lump sum amount of [***] with respect to the change set forth in clause (7) above (PCO#81); (i) a fixed lump sum amount of [***] with respect to the change set forth in clause (8) above (PCO#82); (j) a fixed lump sum amount of [***] with respect to the change set forth in clause (9) above (PCO#83); (k) a fixed lump sum amount of [***] with respect to the changes set forth in clause (10) above; (l) a fixed lump sum amount of [***] with respect to the changes set forth in clause (11) above (PCO#65); (m) a negative fixed lump sum amount of [***] with respect to the changes set forth in clause (12) above ([***] for (PCO#89), [***] for (PCO#90), [***] for (PCO#92), [***] for (PCO#94) and a negative fixed lump sum amount of [***] for (PCO#95)); (n) a fixed lump sum amount of [***] with respect to the changes set forth in clause (13) above (PCO#91)):   


Execution version

 

The adjusted Contract Price, including this Change Order, shall be:

   $ [ ***] 

The original fixed fee for transportation was:

   $ [ ***] 

The net adjustment to the fixed fee by previously executed Change Orders is:

   $ [ ***] 

The fixed fee prior to this Change Order was:

   $ [ ***] 

The fixed fee shall be increased by this Change Order in the amount of:

   $ [ ***] 

The adjusted fixed fee for transportation, including this Change Order, shall be:

   $ [ ***] 

The original not to exceed amount for Transportation Costs was:

   $ [ ***] 

The net adjustment to the not to exceed amount for Transportation Costs by previously executed Change Orders is:

   $ [ ***] 

The adjusted not to exceed amount for Transportation Costs prior to this change order was:

   $ [ ***] 

The not to exceed amount for Transportation Costs shall be increased by this Change Order in the amount of:

   $ [ ***] 

The adjusted not to exceed amount for Transportation Costs, including this Change Order, shall be:

   $ [ ***] 

Exhibit B to this Change Order contains Seller’s cost details for the scope of supply modifications set forth herein for information purposes only.

PROJECT SCHEDULE:

This Change Order has no impact on the Project Schedule or the Milestone Dates.

TERMS AND CONDITIONS:

Buyer and Seller further agree to the following changes to the Agreement:

 

  a.

Clause 6.4(c) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to “[***] Dollars [***]” in its entirety and inserting “[***] Dollars [***]” in its place, and (ii) deleting the reference therein to “[***] [***] Dollars [***]” in its entirety and inserting “[***] Dollars [***]” in its place.


Execution version

 

  b.

Clause 25.3(a)(i) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***] Dollars [***]” in its entirety and inserting “[***] Dollars [***]” in its place.

 

  c.

Clause 25.3(a)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***] Dollars [***]” in its entirety and inserting “[***] Dollars [***]” in its place.

 

  d.

Clause 25.3(b)(i) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to “[***] Dollars [***]” in its entirety and inserting “[***] Dollars [***]” in its place, and (ii) deleting the reference therein to “[***] Dollars [***]” in its entirety and inserting “[***] Dollars [***]” in its place.

 

  e.

Clause 25.3(b)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***] Dollars [***]” in its entirety and inserting “[***] Dollars [***]” in its place.

Seller waives any and all rights to claim any payment or any relief for time for the performance of its obligations for the performance of the scope of the changes that are set forth under this Change Order. This Change Order constitutes compensation in full for Seller for all costs and expenses directly or indirectly attributable to the changes set forth herein, for all delays related thereto, and for performance of the changes within the time stated. Notwithstanding, such adjusted Contract Price does not include any Buyer Taxes which will be added to such Contract Price in accordance with and subject to the terms of the Agreement.

All other terms and conditions of the Agreement remain in effect unless specifically modified herein.

[Signature Page Follows.]


Agreed pursuant to the Agreement by:
Baker Hughes Energy Services LLC     Venture Global Plaquemines LNG, LLC
By:  

/s/ Chris Coffman

    By:  

/s/ Keith Larson

Name:  

Chris Coffman

    Name:  

Keith Larson

Title:  

Vice President

    Title:  

Secretary


Exhibit A

APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

[See attached.]


Execution version

 

APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one (1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement.

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders.

In addition to the amounts shown in the Payment Milestone in Section I.B., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] during the first [***] of the Payment Schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the Transportation Fixed Fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of [***]. In all other cases, Facility-specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Plaquemines Parish sales and use taxes that constitute Buyer Taxes. Any such Plaquemines Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.


Execution version

 

I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of LNTP shall be as indicated in the table below.

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   1    [***]    [***]

[***]

   L1    [***]    [***]

[***]

   2    [***]    [***]

[***]

   3    [***]    [***]


Execution version

 

  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   1    [***]    [***]

[***]

   L1    [***]    [***]

[***]

   2    [***]    [***]

[***]

   3    [***]    [***]


Execution version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   4    [***]    [***]

[***]

   5    [***]    [***]

[***]

   6    [***]    [***]

[***]

   7    [***]    [***]

[***]

   8    [***]    [***]

[***]

   9    [***]    [***]

[***]

   10    [***]    [***]

[***]

   11    [***]    [***]

[***]

   12    [***]    [***]

[***]

   13    [***]    [***]

[***]

   14    [***]    [***]


Execution version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   15    [***]    [***]

[***]

   16    [***]    [***]

[***]

   17    [***]    [***]

[***]

   18    [***]    [***]

[***]

   19    [***]    [***]

[***]

   20    [***]    [***]

[***]

   21    [***]    [***]

[***]

   22    [***]    [***]

[***]

   23    [***]    [***]

[***]

   24    [***]    [***]

[***]

   25    [***]    [***]

[***]

   26    [***]    [***]

[***]

   27    [***]    [***]

[***]

   28    [***]    [***]

[***]

   29    [***]    [***]

[***]

   30    [***]    [***]


Execution version

 

Payment Milestone Notes

1

   [***]

2

   [***]

3

   [***]

4

   [***]

5

   [***]

6

   [***]

7

   [***]

8

   [***]

9

   [***]

10

   [***]

11

   [***]

12

   [***]


Execution version

 

II.

Aggregate Payment Milestone Cap:

The aggregate amount of all Payment Milestones invoiced by Seller as of each month, including all invoices submitted to Buyer in prior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month. For the avoidance of doubt, the Aggregate Payment Milestone Cap shall be inclusive of the LNTP Advance.

 

  A.

[***]

 

Month after Issuance of LNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

  B.

[***]

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

after CO#2

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution version

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

after CO#2

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution version

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

after CO#2

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution version

 

III.

Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29.1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]

where:

[***]

 

Months after issuance of LNTP or

issuance of a Suspension Notice, as

Applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution version

 

  4.

If LNTP is issued and FNTP is subsequently issued prior to the termination of the Agreement, the Maximum Termination Fee shall be as follows; provided, however, that if (a) no LNTP is issued but the FNTP is issued or (b) FNTP is issued less than [***] after the issuance of LNTP, in either case, the Maximum Termination Fee set forth in the first [***] in the table below shall be increased by [***].

 

Months after issuance of LNTP or

FNTP or issuance of a Suspension

Notice, as applicable

  

Maximum Termination Fee

(After CO#2)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]


Execution version

 

Exhibit B

Cost Details

[Omitted]

Exhibit 10.44

Certain identified information has been omitted from this document because (i) it is not material and is the type the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy, and has been marked with “[***]” to indicate where omissions have been made.

CHANGE ORDER NO. 03

UNDER THE PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

August 29, 2024

Reference is made to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of August 5, 2022 (as amended, the “Agreement”), by and between Venture Global Plaquemines LNG, LLC, a Delaware limited liability company (“Buyer”) and Baker Hughes Energy Services LLC, a Delaware limited liability company (“Seller”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. Except to the extent as may be specifically described in this Change Order, the changes set forth herein do not relieve Seller of any of its responsibilities described in the Agreement.

Once this Change Order is executed by both Parties, and except to the extent set forth herein, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Seller fully for all such effects.

SCOPE:

This Change Order modifies Appendix C (Scope of Supply & Project Schedule) as set forth below:

 

1.

Section 1.2 (Description of the Liquefaction Train sub-systems) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following bullet point after the last bullet point in the sub-section entitled “Cold Box Equipment”:

[***]

 

2.

Section 1.3 (Electrical System Scope) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet point immediately after the last bullet point of the section:

[***]


Execution Version

 

3.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last bullet in the subsection entitled, “Others”:

[***]

CONTRACT PRICE TRUE-UP

Buyer and Seller agree to an adjustment to the Contract Price (on a lump sum basis) relating to the provisions set forth in Part B of Clause 7.1 (Definition of Contract Price) of Appendix A (General Terms & Conditions) to the Agreement. The Contract Price shall be increased by an amount equal to the aggregate amount of [***] in final and full satisfaction of such requirement.

 

CONTRACT PRICE:

  

The original Contract Price was:

   $ [***]  

The net adjustment to the Contract Price by previously executed Change Orders is:

   $ [***]  

The Contract Price prior to this Change Order was:

   $ [***]  

The Contract Price shall be increased by this Change Order in the amount (the “Change Order Price”) of:

   $ [***]  
(comprised of: (a) a fixed lump sum amount of $[***], with respect to the change set forth in clause 1 above (PCO#l11 Rev.00); (b) a fixed lump sum amount of $[***] with respect to the change set forth in clause 2 above (PCO#l00 Rev.01); (c) a fixed lump sum amount of $[***] with respect to the change set forth in clause 3 above (PCO# 108 Rev.02); and (d) a fixed lump sum amount of $[***] with respect to the Contract Price true-up above (PCO#l07 Rev.00)).   


Execution Version

 

The adjusted Contract Price, including this Change Order, shall be:

   $ [***]  

The original fixed fee for transportation was:

   $ [***]  

The net adjustment to the fixed fee by previously executed Change Orders is:

   $ [***]  

The fixed fee prior to this Change Order was:

   $ [***]  

The fixed fee shall be increased by this Change Order in the amount of:

   $ [***]  

The adjusted fixed fee for transportation, including this Change Order, shall be:

   $ [***]  

The original not to exceed amount for Transportation Costs was:

   $ [***]  

The net adjustment to the not to exceed amount for Transportation Costs by previously executed Change Orders is:

   $ [***]  

The adjusted not to exceed amount for Transportation Costs prior to this change order was:

   $ [***]  

The not to exceed amount for Transportation Costs shall be increased by this Change Order in the amount of:

   $ [***]  

The adjusted not to exceed amount for Transportation Costs, including this Change Order, shall be:

   $ [***]  

Exhibit B to this Change Order contains Seller’s cost details for the scope of supply modifications set forth herein for information purposes only.

PAYMENT MILESTONES:

This Change Order modifies Appendix B. Attached as Exhibit A to this Change Order is a revised version of Appendix B (Pricing; Payment Terms & Cancellation Schedule), which supersedes and replaces the existing Appendix B (Pricing; Payment Terms & Cancellation Schedule) in its entirety.


Execution Version

 

PROJECT SCHEDULE:

This Change Order has no impact on the Project Schedule or the Milestone Dates.

TERMS AND CONDITIONS:

Buyer and Seller further agree to the following changes to the Agreement:

 

  a.

Clause 6.4(c) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to “[***]” in its entirety and inserting “[***]” in its place, and (ii) deleting the reference therein to “[***]” in its entirety and inserting “[***]” in its place.

 

  b.

Clause 25.3(a)(i) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***]” in its entirety and inserting “[***]” in its place.

 

  c.

Clause 25.3(a)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***]” in its entirety and inserting “[***]” in its place.

 

  d.

Clause 25.3(b)(i) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to “[***]” in its entirety and inserting “[***]” in its place, and (ii) deleting the reference therein to “[***]” in its entirety and inserting “[***]” in its place.

 

  e.

Clause 25.3(b)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***]” in its entirety and inserting “[***]” in its place.


Execution Version

 

Seller waives any and all rights to claim any payment or any relief for time for the performance of its obligations for the performance of the scope of the changes that are set forth under this Change Order. This Change Order constitutes compensation in full for Seller for all costs and expenses directly or indirectly attributable to the changes set forth herein, for all delays related thereto, and for performance of the changes within the time stated. Notwithstanding, such adjusted Contract Price does not include any Buyer Taxes which will be added to such Contract Price in accordance with and subject to the terms of the Agreement.

All other terms and conditions of the Agreement remain in effect unless specifically modified herein.

[Signature Page Follows.]


Agreed pursuant to the Agreement by:      
Baker Hughes Energy Services LLC     Venture Global Plaquemines LNG, LLC
By:  

/s/ Jeff Hoke

    By:  

/s/ Keith Larson

Name:   Jeff Hoke     Name:   Keith Larson
Title:   Project Director     Title:   General Counsel and Secretary


Exhibit A

APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

[See attached.]


Execution Version

APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one (1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement.

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders.

In addition to the amounts shown in the Payment Milestone in Section I.B., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] during the first [***] of the Payment Schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the Transportation Fixed Fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of [***]. In all other cases, Facility-specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Plaquemines Parish sales and use taxes that constitute Buyer Taxes. Any such Plaquemines Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.


Execution Version

 

I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of LNTP shall be as indicated in the table below.

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   1    [***]    $[***]

[***]

   L1    [***]    $[***]

[***]

   2    [***]    $[***]

[***]

   3    [***]    $[***]


Execution Version

 

  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   1    [***]    $[***]

[***]

   L1    [***]    $[***]

[***]

   2    [***]    $[***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   3    [***]    $[***]

[***]

   4    [***]    $[***]

[***]

   5    [***]    $[***]

[***]

   6    [***]    $[***]

[***]

   7    [***]    $[***]

[***]

   8    [***]    $[***]

[***]

   9    [***]    $[***]

[***]

   10    [***]    $[***]

[***]

   11    [***]    $[***]

[***]

   12    [***]    $[***]

[***]

   13    [***]    $[***]

[***]

   14    [***]    $[***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   15    [***]    $[***]

[***]

   16    [***]    $[***]

[***]

   17    [***]    $[***]

[***]

   18    [***]    $[***]

[***]

   19    [***]    $[***]

[***]

   20    [***]    $[***]

[***]

   21    [***]    $[***]

[***]

   22    [***]    $[***]

[***]

   23    [***]    $[***]

[***]

   24    [***]    $[***]

[***]

   25    [***]    $[***]

[***]

   26    [***]    $[***]

[***]

   27    [***]    $[***]

[***]

   28    [***]    $[***]

[***]

   29    [***]    $[***]

[***]

   30    [***]    $[***]

[***]

   31    [***]    $[***]


Execution Version

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   32    [***]    $[***]

[***]

   33    [***]    $[***]

[***]

   34    [***]    $[***]

 

Payment Milestone Notes

      

1

   [***]

2

   [***]

3

   [***]

4

   [***]

5

   [***]

6

   [***]

7

   [***]

8

   [***]


Execution Version

 

Payment Milestone Notes

9

   [***]

10

   [***]

11

   [***]

12

   [***]


Execution Version

 

II.

Aggregate Payment Milestone Cap:

The aggregate amount of all Payment Milestones invoiced by Seller as of each month, including all invoices submitted to Buyer in prior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month. For the avoidance of doubt, the Aggregate Payment Milestone Cap shall be inclusive of the LNTP Advance.

 

  A.

[***]

 

Month after Issuance of LNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

 

  B

[***]

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

after C0#3

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]


Execution Version

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

after C0#3

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]


Execution Version

 

Month after Issuance of LNTP or

FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

after C0#3

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]


Execution Version

 

III.

Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29.1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]

where:

[***]

 

Months after issuance of LNTP or

issuance of a Suspension Notice, as

Applicable

  

Maximum Termination Fee

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]


Execution Version

 

4.

If LNTP is issued and FNTP is subsequently issued prior to the termination of the Agreement, the Maximum Termination Fee shall be as follows; provided, however, that if (a) no LNTP is issued but the FNTP is issued or (b) FNTP is issued less than [***] after the issuance of LNTP, in either case, the Maximum Termination Fee set forth in the first [***] in the table below shall be increased by [***].

 

Months after issuance of LNTP or FNTP or

issuance of a Suspension

Notice, as applicable

  

Maximum Termination Fee

(After C0#3)

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]


Execution Version

 

Exhibit B

Cost Details

 

[Omitted]

Exhibit 10.45

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

THIS PURCHASE ORDER CONTRACT FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM (hereinafter this “Agreement”) is entered into as of April 7, 2023 (the Effective Date”) by and between BAKER HUGHES ENERGY SERVICES LLC, a limited liability company organized and existing under the laws of the State of Delaware, with an address and place of business at 17021 Aldine Westfield Road, Houston, Texas 77073 (hereinafter the “Seller”), and VENTURE GLOBAL CP2 LNG, LLC, a limited liability company organized and existing under the laws of the State of Delaware, with an address at 1001 19th Street North, Suite 1500, Arlington, VA 22209 (hereinafter the “Buyer”).

The Buyer and the Seller are referred to herein individually as a “Party” and collectively as the “Parties”.

RECITALS

WHEREAS, Buyer intends to develop, construct and operate a liquefied natural gas (“LNG ”) export facility and terminal on a site adjacent to the Calcasieu Ship Channel, in Cameron Parish, Louisiana, south of Lake Charles, Louisiana, U.S.A. (as defined in Appendix A (General Terms & Conditions);

WHEREAS, Seller designs, engineers, fabricates and manufactures certain natural gas liquefaction equipment in Seller’s affiliated manufacturing facilities;

WHEREAS, Seller sells Liquefaction Train Systems, as defined in Appendix A (General Terms & Conditions);

WHEREAS, Buyer desires to purchase the Liquefaction Train System from Seller for deployment at the Facility, under the terms and conditions set forth herein; and

WHEREAS, Seller is providing, subject to the terms and conditions of this Agreement, an Unconditional Performance Obligation (as defined herein) with production and efficiency standards for the Liquefaction Train System forming part of the process system of the Facility.

NOW, THEREFORE, in consideration of these Recitals, the mutual covenants, promises and agreements contained herein, and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound, the Parties agree as follows:

 

1.

SCOPE OF SUPPLY

Seller agrees to manufacture, sell and deliver the Liquefaction Train System to Buyer as set forth in Appendix C (Scope of Supply & Project Schedule) to this Agreement.

 

2.

PRICE AND PAYMENT

In consideration of the supply of a Liquefaction Train System as described in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule), the Buyer will pay to the Seller the contract price in the increments and on the payment schedule as specified in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule). Termination and cancellation charges shall be as specified in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule).


3.

PERIOD OF PERFORMANCE

Seller shall complete the performance of all of its obligations set forth in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule) in accordance with the activity completion and delivery schedule described in Appendix C (Scope of Supply & Project Schedule) and the terms of this Agreement. The Liquefaction Train System shall be delivered subject to the Incoterms 2020 as described in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule). Buyer shall complete performance of all of its obligations set forth in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule) in accordance with the terms of this Agreement.

 

4.

TERMS AND CONDITIONS

The following terms and conditions are applicable to this Agreement. The Agreement between the Parties shall be comprised of and consists of the following documents (the “Order Documents”), each of which shall be read and construed as an integral part of the Agreement, listed in order of precedence in case of dispute:

 

1.

  

This document;

2.

  

Appendix A:

  

General Terms & Conditions;

3.

  

Appendix B:

  

Pricing; Payment Terms & Cancellation Schedule;

4.

  

Appendix C:

  

Scope of Supply & Project Schedule;

5.

  

Appendix D:

  

Form of Buyer Parent Company Guarantee;

6.

  

Appendix E:

  

Quality Assurance and Quality Control;

7.

  

Appendix F:

  

Performance Tests;

8.

  

Appendix G:

  

Approved Subcontractors;

9.

  

Appendix H:

  

Form of Seller Parent Company Guarantee

10.

  

Appendix I:

  

Form of Change Order;

11.

  

Appendix J:

  

Form of Lien Waivers and Releases;

     J-1    Seller Form of Partial Lien Waiver and Release;
     J-2    Seller Form of Final Lien Waiver and Release;
     J-3    Subcontractor Form of Partial Lien Waiver and Release;
     J-4    Subcontractor Form of Final Lien Waiver and Release;

 

2


12.

  

Appendix K:

  

Transportation Costs; and

13.

  

Appendix L:

  

Liquidated Damage Amounts.

14.

  

Appendix M:

  

Contract Price Adjustments

 

5.

LIMITED RECOURSE

Except to the extent as otherwise provided in any parent guarantee provided to Seller under this Agreement, in the event of non-performance by Buyer of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (a) any assets or properties of any of the shareholders, members or partners of the Buyer, (b) any Affiliate of Buyer or (c) any officers, directors or employees thereof, and no judgment relating to the obligations of Buyer under this Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of Buyer or any other officer, employee or director past, present or future of the Buyer or any of its shareholders, members, partners or Affiliates. Except to the extent as otherwise provided in any parent guarantee provided to Buyer under this Agreement, in the event of non-performance by Seller of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (a) any assets or properties of any of the shareholders, members or partners of the Seller, (b) any Affiliate of Seller or (c) any officers, directors or employees thereof, and no judgment relating to the obligations of Seller under this Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of the Seller or any other officer, employee or director past, present or future of the Seller or any of its shareholders, members, partners or Affiliates.

 

6.

ENTIRE AGREEMENT

The Order Documents making up the Agreement, excluding for the avoidance of doubt that certain Fourth Amended and Restated Letter of Agreement, dated as of April 7, 2023, by and between Seller and VGLNG, (as further amended, amended and restated, supplemented, or otherwise modified from time to time, the “Letter of Agreement”), constitute and represent the entire agreement between the Parties and supersede in their entirety any and all prior agreements or understandings concerning the subject matter hereof, and no modification, amendment, revision, waiver, or other change shall be binding on either Party unless consented to in writing by the Parties or their authorized representatives. Any oral or written representation, warranty, course of dealing or trade usage not contained or referenced herein shall not be binding on either Party. Each Party agrees that it has not relied on, or been induced by, any representations of the other Party not contained in this Agreement.

 

7.

GOVERNING LAW; DISPUTE RESOLUTION

This Agreement shall be subject to the dispute resolution and governing law provisions as further described in Clause 20 and Clause 21 of Appendix A (General Terms & Conditions).

 

3


8.

INTERPRETATION

Capitalized terms used in this Agreement that are not otherwise defined shall have the meaning given in Appendix A (General Terms & Conditions) and the rules of interpretation set forth in Clause 1.2 of Appendix A (General Terms & Conditions) shall apply to this Agreement.

[SIGNATURES APPEAR ON THE FOLLOWING PAGE]

 

4


IN WITNESS WHEREOF the Parties have caused this Agreement to be executed by their authorized representatives as of the Effective Date.

 

SELLER:     BUYER:
BAKER HUGHES ENERGY SERVICES LLC     VENTURE GLOBAL CP2 LNG, LLC
By:  

/s/ Marco Caccavale

    By:  

/s/ Keith Larson

Name:   Marco Caccavale     Name:   Keith Larson
Title:   President     Title:   Secretary

 

[Signature Page to Purchase Order Contract for the Sale of Liquefaction Train System]


APPENDIX A

GENERAL TERMS & CONDITIONS

 

1.

DEFINITIONS AND INTERPRETATION

 

1.1

Definitions.

Unless otherwise defined elsewhere in the Agreement, the following terms shall have the following meanings:

Affiliate” with respect to a Party means an entity (including without limitation any individual, corporation, partnership, limited liability company, association or trust) controlling, controlled by or under common control with that Party. As used herein, “control” means the possession, directly or indirectly, of the power to direct or cause the direction of the management of policies of such Party, whether through the ownership of voting securities or other interest, by contract or otherwise. For the avoidance of doubt, for the purposes of the Agreement, Venture Global Calcasieu Pass, LLC and Venture Global Plaquemines LNG, LLC shall not be deemed to be Affiliates of Buyer.

Aggregate Delivery Delay Liquidated Damages Cap” means an amount equal to [***] of the Contract Price.

Aggregate Performance Delay Liquidated Damages Cap” means an amount equal to [***] of the Contract Price.

Anti-Corruption Laws” has the meaning given to it in Clause 16.5(b).

Approved Subcontractors” means the Subcontractors listed under “Selected Subcontractors” in Appendix G (Approved Subcontractors) of the Agreement and that are otherwise proposed by Seller and approved by Buyer in accordance with Clause 4.2.

Background Intellectual Property” means all Intellectual Property, relevant to the Agreement, that a Party created or acquired before the Effective Date or that a Party creates or acquires independently of the Agreement and not in the performance of its obligations hereunder.

Bankruptcy Event” means, with respect to a Person, that such Person: (a) files a petition or otherwise commences, or authorizes the commencement of, a proceeding or cause under any bankruptcy, insolvency, receivership or similar law for the protection of creditors; (b) has such a petition filed or proceeding commenced against it, which remains undismissed for ninety (90) Days; (c) files an answer or pleading admitting or failing to contest the material allegations of any such petition; (d) takes any action for its winding up, liquidation or dissolution; (e) is otherwise adjudged bankrupt or insolvent under any bankruptcy, insolvency, receivership or similar law for the protection of creditors; or (f) consents to any of the actions described in clauses (a) through (e) of this definition being taken against it.

 

A-1


BAR Policy” has the meaning given to it in Clause 23.4.

Basis of Design” has the meaning given to it in Appendix C (Scope of Supply & Project Schedule).

Benefitted Party” has the meaning given to it in Clause 8.2.

BH-Transient Liquefaction Train Simulation Model” has the meaning given to it in Clause 18.9.

Bonus Date” has the meaning given to it in Clause 6.7.

Buyer” has the meaning given to it in the preamble of the Agreement.

Buyer Developed Intellectual Property” has the meaning given to it in Clause 18.4.

Buyer Excluded Parties” means Buyer, Owner and each of their Affiliates, Venture Global Calcasieu Pass, LLC, Venture Global Plaquemines LNG, LLC and all other entities directly or indirectly owned by Venture Global LNG, Inc., and each of their subsidiaries, owners, shareholders and all of their respective directors, officers, assigns and employees, and the EPC Contractor (and EPC Contractor’s respective affiliates, subsidiaries, owners, shareholders and its respective directors, officers, assigns and employees).

Buyer Inspection Parties” means Buyer, Owner, Owner’s customers, Lenders, Lender’s Engineer and their respective representatives and agents.

Buyer Parent Company Guarantee” means the guarantee, in the form set out in Appendix D (Form of Buyer Parent Company Guaranty), to be issued by Buyer’s parent company and delivered by Buyer to Seller in accordance with Clause 7.8.

Buyer Parties” means Buyer, Owner, the Lenders and each of their Affiliates and all of their respective directors, officers, agents, advisors, engineers, contractors, consultants, representatives, assigns, employees and any other Person acting on behalf of any of them or in representation, interest, benefit thereto.

Buyer Taxes” means any and all existing or future taxes, Duties, fees, or other charges of any nature (including, but not limited to, ad valorem, consumption, excise, franchise, gross receipts, import, export, license, property, sales and use, stamp, storage, transfer, turnover, or value-added taxes, or other similar taxes, and any and all items of deficiency, penalty, addition to tax, interest, or assessment related thereto), imposed by any Governmental Authority of the United States of America (or any political subdivision thereof) in connection with the execution of the Agreement or the purchase of the Liquefaction Train System, but excluding Seller Taxes.

Buyer’s Representatives” has the meaning given to it in Clause 22.1.

Calcasieu Purchase Order” means the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of September 25, 2018, between Seller and Venture Global Calcasieu Pass, LLC.

 

A-2


Change Order” has the meaning given to it in Clause 24.1.

Cold Box” means the Liquefaction Train cold box, as further described in Appendix C (Scope of Supply & Project Schedule).

Confidential Information” has the meaning given to it in Clause 22.1.

Contract Price” means the aggregate amount stated in Clause 7.1 for the purchase of the Liquefaction Train System, as further described in Appendix B (Pricing; Payment Terms & Cancellation Schedule) and as such amount may be modified pursuant to a Change Order signed by Seller and Buyer in accordance with the requirements of the Agreement.

Costs” means all reasonable and documented expenses, costs and third party disbursements incurred by a Party, but excluding any such expenses, costs and disbursements that are excluded pursuant to Clause 19.3.

Country” means the United States of America.

Credit Rating” means the current (a) rating issued or maintained by S&P or Moody’s with respect to such entity’s long-term senior, unsecured, unsubordinated debt obligations (not supported by third party credit enhancements) or (b) corporate credit rating or long-term issuer rating issued or maintained with respect to such entity by S&P or Moody’s.

Day” means a calendar day, i.e. any twenty-four (24) hour period beginning and ending at 12:00 midnight in the State of Louisiana, unless otherwise specified herein as starting from a specific hour.

Defect” means a failure to meet any warranty set forth in Clause 17.1.

Delay Limit Date” means the date on which Seller has accrued an aggregate amount of Delivery Delay Liquidated Damages in an amount equal to or greater than (a) the applicable Delivery Delay Liquidated Damages Cap, or (b) Aggregate Delivery Delay Liquidated Damages Cap.

Delivery Delay Event” means each instance in which Seller fails to deliver a Liquefaction Train (including its associated Cold Box and E-House) (in its entirety) or Deliverable, as applicable, by its associated Delivery Date.

Delivery Delay Liquidated Damages” has the meaning given to it in Clause 6.4(a).

Delivery Delay Liquidated Damages Cap” means, in respect of each Liquefaction Train (including its associated Cold Box and E-House), an amount equal to (a) [***] of the Aggregate Delivery Delay Liquidated Damages Cap in respect of each of the first [***] Liquefaction Trains to be delivered, and (b) [***] of the Aggregate Delivery Delay Liquidated Damages Cap in respect of each of the subsequent [***] Liquefaction Trains to be delivered.

 

A-3


Deliverables” means all information, including the Technical Documentation, that was first conceived, reduced to practice or created by Seller or its employees or Subcontractors in the performance of its obligations under the Agreement, a list of which is set forth in Appendix C (Scope of Supply & Project Schedule).

Delivery Date” means, for each Liquefaction Train, Cold Box, E-House or Deliverable, as applicable, the date on which such Liquefaction Train, Cold Box, E-House or Deliverable, as applicable, is required to be delivered by Seller to Buyer (pursuant to the Incoterms of the Agreement) in accordance with the Agreement, as further described in the Project Schedule.

Delivery Point” has the meaning given to it in Clause 9.1.

Degradation Factor” has the meaning given to it in Clause 6.7.

Disclosing Party” has the meaning given to it in Clause 22.1.

Dispute” has the meaning given to it in Clause 20.1.

Dollars” means the lawful currency of the United States of America.

Duties” has the meaning given to it in Clause 7.1.

E-House ” means the building in common between two (2) Liquefaction Trains containing the necessary electrical and control panels to operate the system.

EAR” has the meaning given to it in Clause 16.2.

EDR File” has the meaning given to it in Clause 18.6.

Effective Date” has the meaning given to it in the preamble of the Agreement.

EPC Agreement” means the agreement that Owner enters into with one or more Persons for the construction of the Facility.

EPC Contractor” means any Person (other than Owner) that is a party to the EPC Agreement.

Event of Default” means an event of default of Seller described in Clause 28.1 or an event of default of Buyer described in Clause 28.2, which in each case has not been cured within the applicable cure period, if any, as provided by the terms of such Clauses.

Facility” means the initial phase of the LNG export terminal and liquefaction project to be located at the Site.

Factory Acceptance Tests” has the meaning given to it in Clause 14.5.

 

A-4


Finance Agreements” means the agreements entered into or to be entered into between Owner or its Affiliates and the Lenders and the other documents related thereto for the purpose of providing financing, refinancing or other financial services for the Facility.

Financial Closing” means that all of the conditions precedent set forth in the Finance Agreements shall have been satisfied or waived and the Lenders party thereto have disbursed the initial loans thereunder.

FNTP” has the meaning given to it in Clause 6.6.

Force Majeure Event” has the meaning given to it in Clause 33.1.

Force Majeure Report” has the meaning given to it in Clause 33.4.

Governmental Authority” means any federal, state, regional, city or local government, any intergovernmental association or political subdivision thereof, or other governmental, regulatory or administrative agency, court, commission, administration, department, board, or other governmental subdivision, legislature, rulemaking board, tribunal or other governmental authority with jurisdiction over Seller, Seller Parties (as may be applicable), Buyer, Owner, EPC Contractor, the Liquefaction Train System(s) or any part thereof or the Site, or any Person acting as a delegate or agent of any Governmental Authority.

Government Official” has the meaning given to it in Clause 16.5(c).

Guaranteed Liquefaction Train Substantial Completion Date” means, with respect to a Liquefaction Train, the last day of the Liquefaction Train Testing Period (as defined in Appendix F (Performance Tests)) for such Liquefaction Train, on which Substantial Completion of the Liquefaction Train for such Liquefaction Train is required to be achieved.

Guaranteed Liquefaction Train System Substantial Completion Date” means the last day of the Liquefaction Train System Testing Period (as defined in Appendix F (Performance Tests)), on which Substantial Completion of the Liquefaction Train System is required to be achieved.

Hazardous Materials” means any chemical, substance, material or emission, including H2S gas, that is or may be regulated, governed, listed or controlled pursuant to any international, national, federal, provincial, state or local statute, ordinance, order, directive, regulation, judicial decision or other legal requirement applicable to Site as a toxic substance, hazardous substance, hazardous material, dangerous or hazardous waste, dangerous good, pesticide, radioactive material, regulated substance or any similar classification, or any other chemical, substance, emission or material, including, without limitation, petroleum or petroleum -derived products or by-products, regulated, governed, listed or controlled or as to which liability is imposed on the basis of potential impact to safety, health or the environment pursuant to any rule or regulation promulgated by any Governmental Authority.

ICC Rules” has the meaning given to it in Clause 20.2.

 

A-5


Instruments of Service” has the meaning given to it in Clause 18.5.

Intellectual Property” means all intellectual property and proprietary rights thereto, including all rights of inventorship and authorship, inventions, patents, patent applications, patent disclosures, know-how, processes, methods, machines, manufactures, designs, compositions of matter, or any new or useful improvement thereof, copyrights, copyright registrations and applications for copyright registration, trademark, trade dress and service mark rights and registrations and applications for registration thereof, and all rights in trade secrets, computer software, data and databases, and mask works, all rights of attribution and integrity and other moral rights and all other intellectual property rights of any type, in each case whether registered or unregistered and including all applications for, and renewals and extensions of such rights and all similar or equivalent rights or forms of protection in any part of the world.

Intellectual Property Claim” means any claim, demand, suit or legal action arising out of or based on any actual or alleged unauthorized disclosure, use or misappropriation of any Intellectual Property, or, any actual or alleged infringement or other violation of any right in, to or under, any Intellectual Property of any other Person that: (a) concerns any materials, deliverables, Work Product or other services provided by Seller, any of its Affiliates, or any Subcontractor under the Agreement; (b) is based upon or arises out of the performance under the Agreement by Seller, any of its Affiliates, or any Subcontractor, including the use of any tools or other implements of construction by Seller, any of its Affiliates, or any Subcontractor; or (c) is based upon or arises out of Buyer’s exercise of its rights pursuant to and in accordance with Clause 18.

Key Personnel” means the project director appointed by Seller pursuant to Clause 3, each deputy project director and any other senior supervisory personnel as agreed between the Parties in writing.

kWh” means kilowatt hour.

Law” means all constitutions, treaties, laws, statutes, edicts, decrees, ordinances, rules, regulations, tariffs, codes, injunctions, writs, requirements, instructions, order and other legal acts of any Governmental Authority or any body under the control of a Governmental Authority.

Lender” means (i) any Person that does or proposes to lend money, finance or provide financial support or equity in any form in respect of the Facility and/or the general business and operations of Owner or each of its Affiliates (including any refinancing thereof), including any export credit agency, funding agency, bondholder, insurance agency, underwriter, investor, commercial lender or similar institution, together with any agent or trustee for such Person and (ii) any provider of any hedging arrangement entered into in connection with the arrangements described in clause (i) above, including an interest rate swap transaction or a forward interest rate swap transaction, in each case together with any agent or trustee for such provider.

Lender’s Engineer” is any Person appointed by the Lenders to represent them on technical matters related to the Facility.

Letter of Agreement” has the meaning set forth in Section 6 of the Agreement.

 

A-6


Lien” means any mortgage, deed of trust, pledge, lien, security interest, option agreement, conditional sale agreement, title retention agreement, claim, equity, attachment, covenant, condition or restriction, charge or encumbrance or any agreement of any kind, in or with respect to any real or personal property.

Liquefaction Train” means the mixed refrigerant compression package, including the Cold Box, surge vessel and other equipment purchased by Buyer from Seller producing approximately [***] MTPA of LNG at design outlet pressure and ambient design conditions of [***] degrees Fahrenheit and [***] relative humidity, at sea level, as further described in Appendix C (Scope of Supply & Project Schedule).

Liquefaction Train Performance Guarantees” means the Liquefaction Train Production Capacity Performance Guarantee and the Liquefaction Train Power Demand Performance Guarantee.

Liquefaction Train Performance Tests” means the Liquefaction Train performance tests described in Appendix F (Performance Tests).

Liquefaction Train Power Demand Minimum Performance Guarantee” means power demand for a Liquefaction Train of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train Production Capacity Performance Guarantee.

Liquefaction Train Power Demand Performance Guarantee” means power demand for a Liquefaction Train of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train Production Capacity Performance Guarantee.

Liquefaction Train Power Demand Liquidated Damages” has the meaning given to it in Clause 25.3(a).

Liquefaction Train Production Capacity Performance Guarantee” means LNG production capacity of [***] MTPA.

Liquefaction Train Production Capacity Liquidated Damages” has the meaning given to it in Clause 25.3(b).

Liquefaction Train System” means the mixed refrigerant compression package, including the Cold Box, surge vessel and other equipment purchased by Buyer from Seller in a configuration of twenty-six (26) Liquefaction Trains capable of producing an aggregate of approximately [***] MTPA of LNG at design conditions, as further described in Appendix C (Scope of Supply & Project Schedule).

Liquefaction Train System Performance Guarantees” means the Liquefaction Train System Production Capacity Performance Guarantee, the Liquefaction Train System Power Demand Performance Guarantee, the Refrigerant Losses Performance Guarantee and the LNG Quality Performance Guarantee.

 

A-7


Liquefaction Train System Performance Delay Liquidated Damages Cap” means an amount equal to [***] of the Aggregate Performance Delay Liquidated Damages Cap.

Liquefaction Train System Performance Tests” means the Liquefaction Train System performance tests described in Appendix F (Performance Tests).

Liquefaction Train System Power Demand Minimum Performance Guarantee” means power demand for the Liquefaction Train System of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train System Production Capacity Performance Guarantee.

Liquefaction Train System Power Demand Performance Guarantee” means power demand for the Liquefaction Train System of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train System Production Capacity Performance Guarantee.

Liquefaction Train System Power Demand Liquidated Damages” has the meaning given to it in Clause 25.3(a).

Liquefaction Train System Production Capacity Performance Guarantee” means LNG production capacity for the Liquefaction Train System of [***] MTPA and [***] at [***] and [***], without considering the maintenance cycle for the Liquefaction Trains.

Liquefaction Train System Production Capacity Liquidated Damages” has the meaning given to it in Clause 25.3(b)(ii).

Liquidated Damages” means Delivery Delay Liquidated Damages, Performance Delay Liquidated Damages and the Performance Liquidated Damages, collectively.

Liquidated Damages Cap” means an amount equal to [***] of the Contract Price.

LNG” has the meaning given to it in the Basis of Design.

LNG Quality Performance Guarantee” means that the LNG composition meets the criteria in Annex C-2 of Appendix C (Scope of Supply & Project Schedule).

LNG Quality Liquidated Damages” has the meaning given to it in Clause 25.3(b)(ii).

LNTP” has the meaning given to it in Clause 6.6.

Losses” means any and all losses, liabilities, damages, costs, charges, expenses, fines, interest, awards, penalties and taxes, which are the result of or arise in connection with any actions, suits, claims, demands, causes of action, litigation, lawsuits, administrative proceedings or administrative investigations.

Major Component” has the meaning given to it in Clause 4.2.

 

A-8


Major Subcontractor” means any Subcontractor identified in Appendix G having a contract with Seller in relation to Seller’s performance of the Agreement with an aggregate value in excess of One Million Dollars ($1,000,000).

Maximum Termination Fee” has the meaning given to it in Clause 29.2.

Milestone” means an event that is identified as a milestone in the Project Schedule.

Minimum Performance Guarantees” means the Liquefaction Train Power Demand Minimum Performance Guarantee, the Liquefaction Train System Power Demand Minimum Performance Guarantee, and the Refrigerant Losses Performance Guarantee.

Mixed Refrigerant” means a mixture of gases or liquids, including ethylene, propane, i- pentane, nitrogen and other gases as may be required to operate a Liquefaction Train.

Module” means the natural gas liquefaction module forming part of a Liquefaction Train, as further described in Appendix C (Scope of Supply & Project Schedule).

Month” means a calendar month according to the Gregorian Calendar beginning at 12:00 midnight in the State of Louisiana, on the last Day of the preceding month and ending at 12:00 midnight in the State of Louisiana, on the last Day of the current month, unless otherwise specified herein as from another Day to the Day preceding the same Day of following Month.

Moody’s” means Moody’s Investor Services, Inc. and any successor thereto.

MTPA” means million Tonnes of LNG per annum.

Notice of Dispute” has the meaning given to it in Clause 20.1.

Operation And Maintenance Manuals” means the manuals described as such in Appendix C (Scope of Supply & Project Schedule).

Other Party” has the meaning given to in Clause 8.2.

Outside Intellectual Property” has the meaning given to it in Clause 18.6.

Owner” means Venture Global CP2 LNG, LLC and any of its successors and assigns.

Party” or “Parties” has the meaning given to it in the preamble of the Agreement.

Payment Milestone” means the event or group of events to be achieved in order to entitle Seller to invoice the payment, as listed in Appendix B (Pricing; Payment Terms & Cancellation Schedule).

Payment Schedule” has the meaning given to it in Clause 7.1.

 

A-9


Performance Delay Liquidated Damages” means the Liquefaction Train Production Capacity Liquidated Damages, the Liquefaction Train System Production Capacity Liquidated Damages and the LNG Quality Liquidated Damages.

Performance Delay Liquidated Damages Cap” means: (a) in respect of each Liquefaction Train, an amount equal to (i) [***] of the Aggregate Performance Delay Liquidated Damages Cap in respect of each of the first [***] Liquefaction Trains to be performance tested and (ii) [***] of the Performance Delay Liquidated Damages Cap in respect of each of the subsequent [***] Liquefaction Trains to be performance tested; and (b) in respect of the Liquefaction Train System Production Capacity Performance Guarantee and the LNG Quality Performance Guarantee, collectively, an amount equal to [***].

Performance Guarantees” means the Liquefaction Train Performance Guarantees and the Liquefaction Train System Performance Guarantees.

Performance Liquidated Damages” means the Liquefaction Train Power Demand Liquidated Damages and the Liquefaction Train System Power Demand Liquidated Damages.

Performance Liquidated Damages Cap” means an amount equal to [***].

Performance Tests” means the Liquefaction Train Performance Tests and the Liquefaction Train System Performance Tests.

Person” means any individual, corporation, partnership, joint venture, limited liability company, association, joint stock company, trust, unincorporated organization, entity, government or other political subdivision.

PIS Purchase Order” means that certain Purchase Order Contract for the Sale of Power Island System to be entered into by Seller and Buyer in relation to the sale of a power island described therein by Seller to Buyer for the Facility.

Plaquemines Purchase Orders” means that certain (a) Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January 19, 2022, between Seller and Venture Global Plaquemines LNG, LLC and (b) Purchase Order Contract for the Sale of Liquefaction Train System, dated as of August 5, 2022, between Seller and Venture Global Plaquemines LNG, LLC.

Pre-LNTP” has the meaning given to it in Clause 6.6.

Preservation Agreement” means the agreement that Buyer and Seller may negotiate and enter into pursuant to which (a) some or all of the Liquefaction Trains will be stored in a storage facility meeting Seller’s requirements for [***] or more, up to [***], and (b) Seller will for commercially reasonable market-based rates provide Buyer with preservation and maintenance services for such Liquefaction Trains while such Liquefaction Trains are in stored in the storage facility.

 

A-10


Project Schedule” means the activity completion and delivery schedule set forth in Appendix C (Scope of Supply & Project Schedule).

Qualified Financial Institution” means a U.S. commercial bank or a U.S. branch office of a foreign bank having, in either case, (a) assets of at least $10,000,000,000 and (b) a Credit Rating from one or both of S&P and Moody’s, which Credit Rating is at least “A-” from S&P (if such bank has a Credit Rating from S&P) and “A3” from Moody’s (if such bank has a Credit Rating from Moody’s).

Ready for Test” means that the Liquefaction Train or the Liquefaction Train System, as applicable, (i) has been installed and is mechanically complete, (ii) has completed Seller’s commissioning and start-up activities pursuant to the Services Agreement, (iii) is capable of being operated safely in accordance with requirements under the EPC Agreement, and (iv) is ready for the Performance Tests to be performed in accordance with the Agreement.

Rebatable Louisiana Sales and Use Tax” has the meaning given to it in Clause 8.2.

Receiving Party” has the meaning given to it in Clause 22.1.

Refrigerant Losses Performance Guarantee” means the loss in Mixed Refrigerant from compressor seals on one Liquefaction Train of [***] based on a normal back pressure of [***].

Reliability Guarantee” has the meaning given to it in Clause 25.1(g).

Representatives” means (a) in the case of Buyer, Buyer’s Representatives and (b) in the case of Seller, Seller’s Representatives.

SDN” has the meaning given to it in Clause 16.5(a).

S&P” means Standard & Poor’s Corporation and any successor thereto.

Second LTS Purchase Order” means that purchase order contract for the sale of liquefaction train system described therein to be entered into by Seller and Buyer in accordance with the terms of the Letter of Agreement in relation to the second phase of the LNG export terminal and liquefaction project to be located at the Site.

Seller” means Baker Hughes Energy Services LLC, together with its successors and permitted assigns, who shall sell and deliver the Liquefaction Trains under the Agreement.

 

A-11


Seller Competitors” means [***] or any of their respective Affiliates and any other entities that are competitors of Seller [***], as Buyer and Seller may agree from time to time.

Seller Developed Intellectual Property” has the meaning given to it in Clause 18.3.

Seller Excluded Parties” means Seller and its Affiliates and all of their respective directors, officers, assigns and employees and Seller’s Approved Subcontractors, and General Electric Company and each of its subsidiaries, owners, shareholders and all of their respective directors, officers, assigns and employees.

Seller Parent Company Guarantee” means the guarantee, in the form set out in Appendix H (Form of Seller Parent Company Guarantee), to be issued by Seller’s Guarantor and delivered by Seller to Buyer in accordance with Clause 7.9.

Seller’s Guarantor” means Baker Hughes Holdings LLC, a Delaware limited liability company.

Seller’s Know-How” means all of the information, technique and/or know-how related to the design, engineering, manufacturing, construction, operation, maintenance, optimization, repair and servicing of the Liquefaction Train System which was owned by Seller prior to the Agreement or acquired by Seller during performance of the Agreement.

Seller Parties” means Seller and its Affiliates and all of their respective directors, officers, agents, advisors, engineers, contractors, consultants, representatives, assigns, employees and any other Person acting on behalf of any of them or in representation, interest, benefit thereto.

Seller’s Representatives” has the meaning given to it in Clause 22.1.

Seller Taxes” means any and all existing or future (a) corporate and personal income taxes imposed on Seller and its employees by the applicable Laws of any country and (b) taxes, Duties, fees, or other charges of any nature (including, but not limited to, ad valorem, consumption, excise, franchise, gross receipts, import, export, license, property, sales and use, stamp, storage, transfer, turnover, or value-added taxes, or other similar taxes, and any and all items of deficiency, penalty, addition to tax, interest, or assessment related thereto), imposed by any Governmental Authority of any country, other than the United States of America (or any political subdivision thereof), in connection with the execution of the Agreement, Seller’s sale and delivery of the Liquefaction Trains or Seller’s performance of its other obligations under the Agreement.

Serial Defect” has the meaning given to it in Clause 17.2(c).

Services” means all the services to be provided under the attendant and separate Services Agreement.

Services Agreement” means the field services agreement between Buyer, or Owner, and the Services Provider to be entered into on or before Financial Closing under which the Services Provider will for commercially reasonable market based rates provide Buyer, or Owner, with technical field services, training, the on-Site supervision of the installation, start-up, commissioning and testing of the Liquefaction Trains and the oversight of the operation and maintenance of the Liquefaction Trains that commence commercial operations prior to the Substantial Completion of the Facility.

 

A-12


Services Provider” means Seller or Seller’s Affiliate that provides the Services under the Services Agreement.

Site” means the site located in Cameron Parish, Louisiana, south of Lake Charles, Louisiana, adjacent to the site set forth under the Calcasieu Purchase Order, as further described in Appendix C (Scope of Supply & Project Schedule).

Spare Parts” has the meaning given to it in Clause 13.3.

Subcontractor” means any Person to whom any part of Seller’s obligations under the Agreement has been subcontracted to by Seller.

Substantial Completion of the Facility” means “Facility Substantial Completion” as defined in the EPC Agreement.

Substantial Completion of the Liquefaction Train” means that the Liquefaction Train (i) has achieved Ready for Test, (ii) has completed the Liquefaction Train Performance Tests and (iii) either (1) has satisfied all Liquefaction Train Performance Guarantees or (2) has satisfied the Liquefaction Train Power Demand Minimum Performance Guarantee and Seller has paid all payable liquidated damages for the Liquefaction Train Performance Guarantees that were not met.

Substantial Completion of the Liquefaction Train System” means that the Liquefaction Train System (i) has achieved Ready for Test, (ii) has completed the Liquefaction Train System Performance Tests and (iii) either (1) has satisfied all Liquefaction Train System Performance Guarantees or (2) has satisfied the Liquefaction Train System Power Demand Minimum Performance Guarantee and the Refrigerant Losses Performance Guarantee and Seller has paid all applicable liquidated damages for the Liquefaction Train System Performance Guarantees that were not met.

Technical Documentation” means all technical documentation, specifications, samples, patterns, models, calculations, computer programs (software), Operation And Maintenance Manuals and other documents or information of a similar nature, to be submitted by Seller to Buyer in native files, in accordance with Clause 18, and .PDF in accordance with Appendix C (Scope of Supply & Project Schedule). A list of files required to be submitted in native format is set forth in Appendix C (Scope of Supply & Project Schedule).

Termination Fee” has the meaning given to it in Clause 29.2.

Tonne” means metric ton and is defined as 2204.6 lbs.

Transportation Costs” has the meaning given to it in Clause 7.1.

 

A-13


Unconditional Performance Obligation” means Seller’s absolute obligation to achieve (a) the Liquefaction Train Production Capacity Performance Guarantee for each and every Liquefaction Train; (b) the Liquefaction Train System Production Capacity Performance Guarantee; (c) the LNG Quality Performance Guarantee; (d) the Minimum Performance Guarantees; and (e) the Reliability Guarantee.

VGLNG” means Venture Global LNG, Inc.

Warranty Period” means the period, specified as such in Clause 17.1.

Week” means a calendar week consisting of seven (7) Days.

Working Day” means any Day other than a Saturday, or a Sunday or a legal holiday in the State of New York (solely for the purpose of a payment obligation) or the State of Louisiana (with respect to all other obligations).

Work Product” has the meaning given to it in Clause 18.1.

 

1.2

Interpretation

In the Agreement, unless the context otherwise requires or the relevant provision(s) expressly state otherwise:

 

  (a)

the headings to the clauses and the emphasizing are for convenience only and do not affect the interpretation of the Agreement;

 

  (b)

all references to documents or other instruments include all amendments and replacements thereof and supplements thereto;

 

  (c)

all references to any statute or statutory provision shall include references to any statute or statutory provision which amends, extends, consolidates or replaces the same or which has been amended, extended, consolidated or replaced by the same and shall include any orders, regulations, instruments or other subordinate legislation made under the relevant statute;

 

  (d)

reference to a ‘Person’ or ‘Persons’ or a ‘party’ or ‘parties’ includes individuals, bodies corporate, unincorporated associations and partnership and that Person’s or those Persons’ personal representatives, successors and permitted assignees, private or public bodies or individuals;

 

  (e)

any obligation on a Party to do anything shall be deemed to include an obligation to procure such thing to be done; any obligation not to do anything shall be deemed to include an obligation not to permit or not to suffer such thing;

 

  (f)

when a time-limit is determined in Days, it expires at the end of the last Day and it is counted from Day to Day; when it is determined in Months, it is counted from Day of Month to Day of Month; if the last Day of either time-limit is a public holiday, the time-limit is extended to the end of the first Working Day that follows;

 

A-14


  (g)

save exceptions agreed to by Buyer, the only measurement units admitted are the internationally used measurement units of the metric system;

 

  (h)

if any reference is made in the Agreement to Incoterms or any standards such as ISO standards, the particular Incoterms or standards will apply only:

 

  (i)

to the particular item in respect of which they are used; and,

 

  (ii)

to the extent that such application is not conflicting with the content of the Agreement;

 

  (i)

‘including’ shall, unless expressly stated otherwise, mean ‘including without limitation’;

 

  (j)

references to a ‘Clause’ shall be to a clause of the Agreement;

 

  (k)

the singular number includes the plural number and vice versa;

 

  (l)

reference to any gender includes the other;

 

  (m)

‘hereunder,’ ‘hereof,’ ‘hereto’ and words of similar import shall be deemed references to the Agreement as a whole and not to any particular Clause or other provision hereof or thereof;

 

  (n)

the term ‘or’ is not exclusive, regardless of whether ‘and/or’ is used in the applicable provision; and

 

  (o)

if the Buyer assigns the Agreement to the EPC Contractor, all references to “Buyer” hereunder shall be treated as a reference to “EPC Contractor”, and if Buyer does not assign the Agreement to the EPC Contractor, each reference to “Buyer” hereunder shall be treated as a reference to “Owner”.

 

1.3

Communications - Notices

Any notice, instruction, consent, approval, comment, certificate or determination to be given in connection with the Agreement shall be effective only if in writing and addressed to the Person, as each Party or Owner has identified below: (a) on delivery, if delivered personally to the Person; (b) on transmission, if transmitted to the facsimile number of the Person or by electronic mail; and (c) on posting, if by first class or overnight mail (postage prepaid). No change of address for a Party or Owner shall be effective until written notice of the change of address is provided to the other Parties and Owner in accordance with this Clause 1.3.

If to Buyer: [***]

 

A-15


If to Seller: [***]

If to Owner: [***]

 

A-16


1.4

Language

 

  (a)

All correspondence between Buyer and Seller as well as all Technical Documentation and comments thereto and shipping marks shall be in English.

 

  (b)

The Operation and Maintenance Manuals, all markings on equipment, labels, sign-boards, instrument dials, graphical interfaces with the process control system, safety documentation, machine and component name plates shall be in English.

 

1.5

No Joint Venture, Partnership or Association

 

  (a)

The Agreement shall not be interpreted or construed to create an association, joint venture, or partnership between the Parties or to impose any partnership obligation or liability upon either Party.

 

  (b)

Neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.

 

1.6

Parties to act reasonably

 

  (a)

Where reference is made in the Agreement to a Party’s decision, approval, refusal, consent, agreement, act, etc., such shall not be taken, given or withheld unreasonably or unfairly, unless otherwise expressly stated.

 

  (b)

In all cases the Party claiming a breach of the Agreement by the other Party, shall be obligated to make commercially reasonable efforts to mitigate its costs, losses or damages that have occurred or that may occur as a result of such breach.

 

2.

REQUESTS AND CLARIFICATIONS

Seller represents and warrants to Buyer that Appendix C (Scope of Supply & Project Schedule) includes all of the necessary obligations that are required to be performed by Seller in order for the Liquefaction Train System to operate in accordance with the requirements of the Agreement and satisfy the design codes, standards and the Performance Guarantees set forth in the Agreement. The Parties acknowledge and agree that Appendix C (Scope of Supply & Project Schedule) describes the items for the Liquefaction Train System being provided in general, but not in complete detail. The Parties agree that any

 

A-17


specific items not set forth in Appendix C (Scope of Supply & Project Schedule), or any details or clarifications thereto, that are required in order to satisfy the requirements of the Agreement or to satisfy the design codes, standards and the Performance Guarantees set forth in the Agreement, in each case, will not be considered changes to Appendix C (Scope of Supply & Project Schedule), unless they are explicitly excluded from Appendix C (Scope of Supply & Project Schedule), or are changes to the Basis of Design directed by Buyer, or are changes associated with a Change Order issued pursuant to Clause 24, and Seller waives any right to adjust the Contract Price or the Project Schedule with respect thereto. The Parties acknowledge and agree that Appendix C (Scope of Supply & Project Schedule) contains certain single-line diagrams, pipe and instrumentation diagrams and other diagrams and drawings that will change as Seller completes its engineering of the Liquefaction Train System and that any change to such diagrams and drawings, which are not the result of changes to the Basis of Design directed by Buyer, or changes pursuant to the Change Order requirements of Clause 24, will not be changes that will entitle either Party to changes in the Contract Price or an extension of the Project Schedule.

Buyer may issue to Seller requests or non-material clarifications that are not inconsistent with the obligations of Seller under Appendix C (Scope of Supply & Project Schedule) which Buyer may consider necessary or helpful to Seller in the performance of Seller’s obligations under the Agreement. Seller will evaluate Buyer’s requests or clarifications within a reasonable time period and provide feedback in writing to Buyer. Seller agrees to cooperate with Buyer’s other contractors, including the EPC Contractor.

In the event any such request or clarification of Buyer is transmitted orally, Seller may require Buyer to confirm such request or clarification in writing. Seller shall notify Buyer of such requirement to confirm in writing without undue delay but in any event within seven (7) Working Days of receipt of Buyer’s verbal transmission. If Seller has requested such written confirmation, the request or clarification shall not be effective until written confirmation thereof has been received by Seller.

Any such request or clarification from Buyer shall not relieve Seller from its responsibility for delivering the Liquefaction Trains and performing its other obligations in accordance with the Agreement.

Seller and Buyer agree to reasonably cooperate and work together in good faith with the shared objective of using the experience, knowledge and data derived from the performance under the Agreement, the Calcasieu Purchase Order and the Plaquemines Purchase Orders to optimize the project management services, engineering services, procurement, manufacturing and performance of the Liquefaction Train System in combination with the balance of plant of the Facility (excluding Seller’s improvements that are unrelated to and do not impact the performance, reliability or maintenance of the Liquefaction Train System) with the common goals of (a) increasing the operational performance of the Liquefaction Train System and (b) if possible and solely to the extent consistent with clause (a), reducing the Contract Price; provided, however, that Seller and Buyer acknowledge that (i) no particular result is assured or guaranteed from such price optimization efforts and (ii) Seller shall not be permitted to change the means and methods

 

A-18


of its performance or the Basis of Design: (1) in a manner that would deny or reduce the value to Buyer of the benefits of the optimization of the performance of the Liquefaction Train System achieved by Buyer or (2) except as contemplated under Clause 6.6, without the prior written approval of Buyer. Prior to implementation, Buyer shall consult with Seller in respect of any modifications that adversely and materially impact the inlet, exit or throughput conditions of the Liquefaction Train System. Notwithstanding the foregoing, if and to the extent that Seller makes adjustments to its means and methods or design specifications under the Plaquemines Purchase Orders after the Effective Date that relate to Seller achieving the performance guarantees set forth in the Plaquemines Purchase Orders, such adjustments may be incorporated into the Agreement.

 

3.

PROJECT DIRECTOR

Seller shall provide all oversight and superintendence that is necessary for the performance of its obligations, and obligations of its personnel and the personnel of its Subcontractors, under the Agreement. Seller shall appoint by no later than the Effective Date a competent and authorized representative who shall act as project director and devote the necessary time to the oversight and superintendence of the same and who shall have the authority to act on Seller’s behalf under the Agreement and receive, on behalf of Seller, requests or clarifications from Buyer. In addition, to the extent that such persons are still employees of Baker Hughes Company, then Seller shall make available to Buyer for the performance of this Agreement the same senior supervisory personnel that are presently engaged with Venture Global Plaquemines LNG, LLC in respect of the liquefaction trains under the Plaquemines Purchase Orders. The replacement of, or additions to, the Key Personnel shall only be made with persons having qualifications and experience comparable to those being replaced or added to. In connection with any substitution of Key Personnel, Buyer shall (a) include a detailed explanation and reason for the request and the resumes of professional education and experience for a minimum of two (2) candidate(s) of suitable qualifications and experience and (b) discuss such candidates in advance with Buyer in order to allow Buyer to provide feedback and request for clarifications. Seller shall use commercially reasonable efforts to take Buyer’s recommendations into consideration. In addition, Buyer may if it is concerned with the performance of any Key Personnel request the removal of, and Seller shall use commercially reasonable efforts to comply with such request to remove and replace, such Key Personnel; provided that if Buyer reasonably demonstrates that such Key Personnel has: (i) been gravely incompetent or negligent in the performance of his or her duties, or (ii) engaged in activities in material violation of the Law or of any safety and security protocols of Buyer that were communicated to Seller in writing, Seller shall promptly remove such Key Personnel and replace such Key Personnel in accordance with this Clause 3.

 

4.

ASSIGNMENT AND SUBCONTRACTING

 

4.1

Assignment

Buyer shall not transfer or assign the Agreement or any of its rights under or interest in the Agreement (including monies that are due or monies that may be due) without the prior written consent of Seller, which consent shall not be unreasonably withheld, conditioned or delayed; provided, however, that Buyer shall not need the consent of Seller (a) to transfer

 

A-19


or assign the Agreement to its Affiliate (to the extent such Affiliate is organized under the laws of the United States of America), (b) to transfer or assign the Agreement to the EPC Contractor subject to the requirements under this Clause 4.1 or (c) to assign, charge or otherwise encumber the Agreement or any rights or benefits arising thereunder or therefrom by way of collateral in favor of Lenders. Seller may only transfer or assign the Agreement or any of its rights under or interest in the Agreement (including monies that are due or monies that may be due) with the prior written consent of Buyer, which consent shall not be unreasonably withheld, conditioned or delayed; provided, however, that Seller shall not need the consent of Buyer to assign or novate the Agreement to any Affiliate of Seller that is ultimately wholly owned by Baker Hughes Company and assign any receivables due Seller hereunder to one (1) or more Affiliates of Seller or to third parties. The Parties agree to execute such documents as may be necessary to effect any permitted assignments or transfers of the Agreement. In connection with any collateral assignment of the Agreement by Buyer, Seller shall provide any customary agreements, certificates, legal opinions or other documents reasonably required by any Lender. In connection with any assignment of the Agreement to the EPC Contractor by Buyer, Seller shall agree to any modifications to the Agreement that are reasonably requested by the EPC Contractor, so long as such modifications do not impose any additional risk, costs, expenses or liability on Seller or Owner. In the event of a transfer or assignment of the Agreement by (i) Buyer, (A) Buyer’s assignee or transferee shall have financial capabilities, directly or by virtue of credit enhancements or other financial arrangements, that are comparable or better than Buyer’s, as of the Effective Date, and (B) Buyer shall cause the credit support under Clause 7.8 to be maintained or provide Seller with replacement credit support that is reasonably acceptable to Seller and substantially similar as provided to Seller hereunder (in which case, if the conditions of Clause 4.1(i)(A) and (i)(B) are met, any credit support that was provided to Seller prior to such assignment shall be promptly returned by Seller to Buyer) and (ii) Seller, Seller shall cause the credit support under Clause 7.9 to be maintained or provide Buyer with replacement credit support that is reasonably acceptable to Buyer and substantially similar as provided to Buyer hereunder. Any assignment, novation, transfer or other disposal in violation of this Clause 4.1 shall be null and void ab initio and shall not be binding on the Parties. For any assignment by Buyer of the Agreement either to Affiliates, EPC Contractor or any other third parties, Buyer acknowledges that Seller shall perform its standard “Know Your Customer” due diligence (which involves various compliance and financial due diligence) on the proposed assignee and the proposed assignee must satisfy the “Know Your Customer” requirements.

 

4.2

Subcontracting

Seller and Buyer agree that Seller may not utilize the services of any Subcontractors without obtaining Buyer’s prior written approval, which approval may not be unreasonably delayed or withheld. As of the Effective Date, Buyer has agreed that Seller may, subject to the remaining provisions of this Clause 4.2 and Clause 8.4, utilize the services of the Approved Subcontractors listed in Appendix G (Approved Subcontractors). Seller may only utilize the services of the Approved Subcontractors (a) that satisfy Buyer’s quality requirements and (b) in accordance with the requirements set forth in this Clause 4.2. If Seller is considering utilizing the services of any Subcontractor that is not an Approved

 

A-20


Subcontractor, then Seller shall notify Buyer of its proposal for such Subcontractor to become an Approved Subcontractor and furnish to Buyer all information reasonably requested by Buyer with respect to the qualifications of such proposed Subcontractor. Buyer shall have the right, acting reasonably, to reject any such proposed Subcontractor, and Seller shall not enter into any subcontract with such proposed Subcontractor that is rejected by Buyer. If an Approved Subcontractor, that has been selected to provide or is providing equipment, becomes subject to bankruptcy or insolvency proceedings or is unable, in Seller’s reasonable judgment, to supply all of the relevant equipment due to capacity constraints, Seller and Buyer will collaborate to develop a list of three or fewer acceptable Subcontractors to replace or supplement such Approved Subcontractor, and shall amend Appendix G accordingly. If Buyer rejects such proposed Subcontractor and the existing Approved Subcontractors are not acceptable in Seller’s reasonable determination for price, quality or schedule reasons, then Seller shall be entitled to a Change Order for any resulting incremental increase in price or delay in the Delivery Date as a result of Buyer’s rejection of such proposed Subcontractor. Approval of any Subcontractor under this Clause 4.2 shall only be for the portion of Seller’s obligations so approved by Buyer. No subcontract with an Approved Subcontractor shall bind or purport to bind Buyer, but each such subcontract shall contain a provision permitting its assignment to Buyer, Owner or the Lenders upon Buyer’s or Seller’s written request.

Seller acknowledges and agrees that Buyer shall have the right to consent to and approve the supplier of each major component of equipment comprising the Liquefaction Train System, [***] (each a “Major Component”), and confirms the strategy to use the same Approved Subcontractor identified on Appendix G for each item, as identified by its specific Tag Number, for all Liquefaction Trains. To assist Buyer in the selection of Major Components, for each potential vendor or supplier of a Major Component, Seller agrees to provide Buyer with access to: (a) the identity of the potential vendor or supplier; (b) the delivery and schedule terms for the Major Component; (c) in the case of the Cold Boxes and heat exchangers, the price negotiated by Seller for such Major Components; and (d) all technical and performance information for each Major Component requested by Buyer. To the extent a Major Component supplier is changed based on a Buyer directive and, as a result of such change in Major Component supplier, Seller incurs a documented incremental increase in the price of the Major Component or delay in the delivery of the Major Component that adversely affects the Delivery Date, Seller shall be entitled to a Change Order for an equitable adjustment in the Contract Price and the Project Schedule for the applicable Liquefaction Train System.

Seller further acknowledges that it shall notify Buyer before subcontracting with any Major Subcontractor (excluding for the avoidance of doubt any Approved Subcontractor) supplying materials or fabrication services in connection with the performance of the Agreement that is located in Asia. Buyer shall have the right to reject any such Major Subcontractor so long as a reasonably comparable subcontractor located outside of Asia is identified as capable of performing the relevant scope of supply, and in such event Seller

 

A-21


shall not enter into a subcontract with the Asia-based entity. If Buyer has rejected such proposed Major Subcontractor and the comparable subcontractor located outside of Asia that was identified as capable of performing the relevant scope of supply is not acceptable, in Seller’s reasonable determination, for price, quality or schedule reasons (with Seller having validated for Buyer its determination as to such comparable subcontractor), then, unless such comparable subcontractor is an Approved Subcontractor, Seller shall be entitled to a Change Order for any resulting incremental and documented increase in the Contract Price or adjustment to the Project Schedule, in each case as a result of Buyer’s rejection of such proposed Major Subcontractor.

 

4.3

Other

 

  (a)

Seller hereby acknowledges and agrees that the review or acceptance of any contract between Seller and an Approved Subcontractor by Buyer and the acceptance of the Approved Subcontractors shall not: (i) modify or relieve, in any way, the obligations of Seller pursuant to the Agreement; (ii) be raised as a claim or as a defense or counterclaim to any claim in connection with the Agreement; or (iii) constitute any approval or acceptance of the work, services or equipment provided under such subcontract or by such Approved Subcontractor.

 

  (b)

At a minimum, all contracts between Seller and an Approved Subcontractor shall require the following:

 

  (i)

such Approved Subcontractor shall comply with all applicable professional standards, permits and Laws, rules, codes and regulations and with the performance standards of Seller under the Agreement;

 

  (ii)

Buyer and Owner shall have all the inspection rights that Buyer and Owner have under the Agreement;

 

  (iii)

such Approved Subcontractor shall be subject to the applicable labor obligations and the safety and security provisions under the Agreement;

 

  (iv)

such Approved Subcontractor shall provide guarantees and warranties with respect to the work and services performed and the materials provided under such contract;

 

  (v)

such Approved Subcontractor shall (A) obtain and carry the insurance coverages (with limits appropriate to the value of such contract) required of Seller pursuant to Clause 23 from an insurance carrier with an A rating from A.M. Best and naming Buyer as an “additional insured”, and (B) provide certificates of insurance as set forth herein;

 

  (vi)

such contract shall be subject to the dispute resolution procedures as set forth herein;

 

A-22


  (vii)

such Major Subcontractor(s) shall provide the applicable Lien waiver and releases required under Clause 7.6, in connection with each payment to Seller hereunder;

 

  (viii)

such Approved Subcontractor(s) shall grant a license to Buyer in accordance with Clause 18.1 and Clause 18.3;

 

  (ix)

such contract shall be subject to the confidentiality provisions set forth under the Agreement; and

 

  (x)

such contract shall be subject to the anti-corruption provisions set forth in Clause 16.5.

 

  (c)

All contracts between Seller and an Approved Subcontractor must specify that the contractual relationship with such Approved Subcontractor is exclusive to Seller and that such Approved Subcontractor waives any and all rights to demand any payment directly from Buyer and Owner. All contracts between Seller and Approved Subcontractors shall preserve and protect the rights of Buyer and Owner, shall not prejudice such rights and shall require each Approved Subcontractor to enter into similar agreements with its subcontractors. As between Seller and Buyer, Seller shall be solely responsible for the acts, omissions or defaults of the Approved Subcontractors and their agents, representatives and employees. Nothing in the Agreement shall be construed to impose on Buyer or Owner any obligation, liability or duty to an Approved Subcontractor or any other Subcontractor or to create any contractual relationship between any Subcontractor, including any Approved Subcontractor, or other third party and Buyer, including an obligation to pay or to see to the payment of any moneys due any such Subcontractor, Approved Subcontractor or other third party.

 

  (d)

No Approved Subcontractor is intended to be nor shall be deemed a third party beneficiary of the Agreement. In addition to the requirements set forth above, Seller shall include in each contract with an Approved Subcontractor language under which Buyer and Owner shall be made express third party beneficiaries of such contract. If any Approved Subcontractor or proposed Subcontractor refuses to name Buyer and Owner as a third party beneficiary or provide for a right of assignment to Buyer, then Seller shall not use such Subcontractor for any portion of Seller’s obligations hereunder, unless Buyer’s prior written consent is obtained.

 

  (e)

Contingent upon receipt of Buyer’s designation in writing as set forth below, Seller hereby assigns to Buyer (and Buyer’s permitted assigns) all its interest in any contracts with Approved Subcontractors (or any portion thereof to the extent such contracts also relate to other projects of Seller) now existing or hereafter entered into by Seller for performance of any part of the work or services, or provision of any materials under the Agreement. Such assignment of Approved Subcontractor contracts will be effective upon written acceptance by Buyer in writing and only as to those contracts which Buyer designates in such written acceptance.

 

A-23


5.

SCOPE

Seller agrees to have the Liquefaction Modules manufactured at Seller’s Affiliate’s manufacturing facilities located in [***] and to sell and deliver the Liquefaction Trains and provide the associated Technical Documentation to Buyer as set forth in Appendix C (Scope of Supply & Project Schedule) by the respective Delivery Dates, all in compliance with all other obligations under the Agreement.

 

6.

COMPLIANCE WITH TIME-LIMITS

 

6.1

Time for delivery

Seller shall diligently proceed with the performance of its obligations under the Agreement in accordance with the Project Schedule and the other requirements of the Agreement.

 

6.2

Progress of Works – Delay

Seller shall cause each Liquefaction Train, Cold Box and E-House to be delivered on or before the Delivery Date for such Liquefaction Train, Cold Box or E-House. If, at any time, Seller’s actual progress with respect to a Liquefaction Train, Cold Box or E-House is not consistent with meeting the Delivery Date for such Liquefaction Train, Cold Box or E-House, or as from the moment any of Seller’s personnel working on the Liquefaction Train System becomes aware of the fact that a Milestone for a Liquefaction Train, Cold Box or E-House cannot be met that will affect the Delivery Date for a Liquefaction Train, Cold Box or E-House, Seller shall promptly provide written notice to Buyer of such occurrence and shall develop, a recovery plan to overcome the anticipated delay and provide to Buyer, within ten (10) Working Days of such occurrence, a report identifying:

 

  (a)

the likely period of delay;

 

  (b)

the event causing the delay;

 

  (c)

the impact which such event has had or in the opinion of Seller is likely to have or will have on its ability to achieve any of the Milestones;

 

  (d)

the recovery plan developed by Seller to overcome the anticipated delay and the steps which Seller has taken, is taking and will take to mitigate the adverse consequences of such event; and

 

  (e)

further particulars of the consequences of the delay as Seller becomes aware.

Seller shall, in consultation with Buyer, implement the recovery plan and use best efforts to minimize or remove the actual or anticipated delay and any consequences thereof. If Buyer provides notice to Seller that Buyer reasonably believes that the steps proposed by Seller fail to adequately address the anticipated delay in meeting the Milestones as part of the recovery plan developed by Seller, then Seller shall increase its efforts in order to remove or minimize such anticipated delay.

 

A-24


6.3

Restriction on Change Order for Extension of Delivery Date

Seller shall not be entitled to a Change Order for an extension of time under the Agreement and/or reimbursement of Costs to the extent that such extension or reimbursement is due to any act, omission or default on the part of Seller or any Subcontractor.

 

6.4

Delivery Delay Liquidated Damages

 

  (a)

Each Liquefaction Train, Cold Box and E-House, and certain Deliverables have a Delivery Date. If Seller fails to deliver a Liquefaction Train, Cold Box, E-House or such Deliverable by its associated Delivery Date, as the Delivery Date may be extended according to a Change Order, Seller shall be obligated to pay to Buyer liquidated damages (the “Delivery Delay Liquidated Damages”) for delay in achieving the Delivery Date as from the first Day following the scheduled Delivery Date until the Day on which delivery of (i) that specific Liquefaction Train, Cold Box or E-House to the Delivery Point actually occurs, provided that Seller shall not be obligated to pay Delivery Delay Liquidated Damages for any Day (or part thereof) beyond [***] that is required for a Liquefaction Train to clear customs in the Country for reasons that are not attributable to Seller’s or its Subcontractors’ acts or omissions or (ii) that specific Deliverable to Buyer actually occurs.

 

  (b)

The Delivery Delay Liquidated Damages payable by Seller to Buyer for each Day of delay in delivery of a specific Deliverable to Buyer beyond the Delivery Date for such Deliverable is [***] per Day. The aggregate amount of the Delivery Delay Liquidated Damages payable by Seller to Buyer for all Deliverables shall not exceed [***].

 

  (c)

For each Liquefaction Train (including the associated Cold Box or E-House), the liquidated damages payable by Seller to Buyer for each Day of delay in delivery of the specific Liquefaction Train, Cold Box or E-House (in each case, in its entirety) to the Delivery Point beyond the Delivery Date is (i) in respect of the first [***] Liquefaction Trains, Cold Box or E-House to be delivered, an amount equal to: (1) for each of the first [***] Days of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days; (ii) in respect of the subsequent [***] Liquefaction Trains, Cold Boxes or E-Houses, an amount equal to: (1) for each of the first [***] Days of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days.

 

A-25


  (d)

The aggregate amount of Delivery Delay Liquidated Damages payable by Seller to Buyer for (i) each Liquefaction Train (including the associated Cold Box and E-House) shall not exceed the applicable Delivery Delay Liquidated Damages Cap, and (ii) all Liquefaction Trains (including all Cold Boxes and E-Houses) shall not exceed the Aggregate Delivery Delay Liquidated Damages Cap. Liquidated Damages payable by Seller to Buyer shall not exceed the Liquidated Damages Cap. Once Seller has accrued Delivery Delay Liquidated Damages in an amount equal to the Delivery Delay Liquidated Damages Cap or Aggregate Delivery Delay Liquidated Damages Cap, as applicable, Buyer shall be entitled to exercise the rights provided in Clause 6.5.

 

  (e)

Buyer shall invoice Seller for any amounts due for Delivery Delay Liquidated Damages. Payment of any Delivery Delay Liquidated Damages shall occur by Seller within [***] following the date Buyer submits to Seller an invoice therefore. Buyer and Seller agree that the amount of Delivery Delay Liquidated Damages are reasonable in light of the anticipated harm caused by the breach of duty related thereto and the difficulties of proof of loss and inconvenience or non-feasibility of obtaining any adequate remedy with respect to the actual level of damages Buyer is likely to suffer as the result of a Delivery Delay Event, and the Parties are estopped from contesting the validity or enforceability of such liquidated damages. Except as provided in Clause 28.1 and Clause 28.3, the payment of Delivery Delay Liquidated Damages during the period prior to the Delay Limit Date shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for any Delivery Delay Event. In the event the Delivery Delay Liquidated Damages provisions in the Agreement are found for any reason to be void, invalid or otherwise inoperative so as to disentitle Buyer from claiming and recovering Delivery Delay Liquidated Damages from Seller for any Delivery Delay Event, Buyer shall, in addition to the remedies set forth below in Clause 6.5, be entitled to claim against Seller and recover for damages for any Delivery Delay Event; provided that such damages shall not exceed the limitations set forth in Clause 6.4(d).

 

6.5

Delays - Other remedies

Notwithstanding Clause 6.2, if Seller has reached the Delay Limit Date, Buyer may by notice to Seller, at Buyer’s sole discretion:

 

  (a)

require Seller to agree, within [***] of Buyer’s demand, to remedy the Delivery Delay Event, within the period of time identified by Buyer, at Buyer’s sole discretion. If Seller fails to agree within [***] of Buyer’s demand, or fails to remedy the Delivery Delay Event within such agreed period(s), Buyer shall be free to exercise its rights or remedies under clause (b) hereafter; or

 

A-26


  (b)

terminate the Agreement in accordance with Clause 28.1(g) and seek to recover from Seller Buyer’s damages pursuant to Clause 28.3 (subject to the limit of liability cap in Clause 19.2) arising from the applicable Delivery Delay Event, and, upon such termination by Buyer, Seller shall deliver to Buyer the portions of the Liquefaction Train System for which Seller has received payment and which have not been delivered to the Delivery Point; provided, however, that Buyer shall not be entitled to terminate the Agreement for so long as Seller continues to pay Buyer the applicable Delivery Delay Liquidated Damages, despite the fact that the aggregate amount of Delivery Delay Liquidated Damages paid by Seller have exceeded the limitations set forth in Clause 6.4(d).

 

6.6

Issuance of LNTP and FNTP

The Project Schedule assumes that (a) a pre-limited notice to proceed (“Pre-LNTP”) authorizing the scope described in Appendix B (Pricing, Payment Terms & Cancellation Schedule) and Appendix C (Scope of Supply & Project Schedule) will be issued by Buyer no later than [***] Days following the execution of the Agreement and no later than [***] Days prior to the issuance of the limited notice to proceed (“LNTP”) authorizing the scope described in Appendix B (Pricing, Payment Terms & Cancellation Schedule) and Appendix C (Scope of Supply & Project Schedule), and (b) a limited notice to proceed (“LNTP”) authorizing the scope described in Appendix B (Pricing, Payment Terms & Cancellation Schedule) and Appendix C (Scope of Supply & Project Schedule) will be issued by Buyer no later than [***] Days following the issuance of the Pre- LNTP and no later than [***] Days prior to the issuance of full notice to proceed authorizing Seller to proceed with the full scope of work under the Agreement (“FNTP”). If the Pre-LNTP is issued less than [***] Days prior to the issuance of the LNTP, the Project Schedule shall be extended day for day for each day that the Pre-LNTP was issued less than [***] Days prior to the issuance of the LNTP. If the LNTP is issued less than [***] Days prior to the issuance of the FNTP, the Project Schedule shall be extended day for day for each day that the LNTP was issued less than [***] Days prior to the issuance of the FNTP. In the event that neither of Pre-LNTP or LNTP is issued prior to issuance of the FNTP, the Project Schedule shall be extended by [***] Days. Seller and Buyer acknowledge and agree that the amount payable under the Pre-LNTP shall be [***], and the amount payable under the LNTP shall be [***].

If Buyer fails to issue the LNTP within [***] Days following issuance of Pre-LNTP or fails to issue the FNTP within [***] Days following issuance of LNTP, Seller, to the extent it reasonably determines that any actions can be taken prior to the issuance of FNTP to preserve schedule integrity with respect to critical Subcontractors and/or Major Components, and facilitate the procurement of any such critical long-lead time equipment and materials, shall notify Buyer of any such potential actions together with supporting cash flow and schedule analysis. The Parties shall promptly and jointly consider such actions, and Buyer may request that Buyer’s personnel be included and participate in any exchanges and discussions with any such Major Subcontractors.

 

A-27


If Buyer fails to issue the FNTP within [***] Days following the Effective Date, Seller shall be entitled to a Change Order for, if the Project Schedule is adversely affected, an equitable adjustment to the Project Schedule. If Buyer fails to issue the FNTP within [***] Days following the Effective Date, the senior management of Buyer and Seller shall meet within [***] Days thereafter to discuss when, if at all, the FNTP will be issued. If, after the senior management meeting there is no mutual agreement on extending the time for issuance of the FNTP, either Buyer or Seller may terminate the Agreement in which case Buyer shall pay Seller the applicable Termination Fee. Buyer may issue additional LNTPs for scope beyond what is provided in Appendix C (Scope of Supply & Project Schedule) pursuant to a Change Order issued pursuant to Clause 24.1.

 

6.7

Delivery Bonus

If Seller delivers a Liquefaction Train and associated Cold Box and E-House to Buyer at the Delivery Point on or before the applicable bonus date set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (each, a “Bonus Date”) for such Liquefaction Train, Cold Box or E-House, then Buyer shall pay to Seller the applicable bonus amount set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) for each such Liquefaction Train and associated Cold Box and E-House; provided that each of such bonus amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement. If Seller delivers a Liquefaction Train and associated Cold Box and E-House before the applicable Delivery Date but after the applicable Bonus Date, the amount payable to Seller in respect of such Liquefaction Train and associated Cold Box and E-House shall be reduced by an amount equal to the applicable amount set forth Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (in each case, the “Degradation Factor”) multiplied by the number of days from the Bonus Date to the later of the actual date of delivery of such Liquefaction Train to the Delivery Point or the actual date of delivery of the Cold Box and E-House. If any of the Liquefaction Trains, the associated Cold Boxes or the associated E-Houses is not delivered to the Delivery Point in its entirety on or before the applicable Delivery Date, then no bonus amount shall be earned or due.

In no event shall the total aggregate amount of all bonus amounts paid by Buyer under this Clause 6.7 exceed [***]. For the purposes of this Clause 6.7 only, Seller shall be deemed to have delivered any Liquefaction Train described in this Clause 6.7 that is delivered to Buyer at the Delivery Point on or before the date that is at least [***] Days prior to the relevant Delivery Date for such Liquefaction Train in the Project Schedule notwithstanding that certain minor items forming a part of the Liquefaction Train have not been delivered to Buyer at the Delivery Point by such date; provided that (i) the Lender’s Engineer has confirmed to Buyer in writing (upon Buyer’s request) that the absence of such minor items would not reasonably be expected to adversely impact the project schedule for testing, commissioning, safety or operability of such Liquefaction Train and (ii) all such minor items are delivered to Buyer at the Delivery Point not later than the relevant Delivery Date for such Liquefaction Train in the Project Schedule or such other date as mutually agreed by the Parties in writing. Amounts earned by Seller pursuant to this Clause 6.7 shall be

 

A-28


due and payable by Buyer to Seller upon completion of delivery by Seller of the Liquefaction Train System and all Components (as such term is defined in the PIS Purchase Order) of the power island system in accordance with the PIS Purchase Order and the finalization of a Change Order within [***] days of such delivery.

 

7.

CONTRACT PRICE AND PAYMENT

 

7.1

Definition of Contract Price

The Contract Price is equal to the sum of [***]. The Contract Price, payment terms and cancellation schedule/charges for each individual Liquefaction Train is detailed in Appendix B (Pricing; Payment Terms & Cancellation Schedule). The Contract Price shall not include any duties and tariffs paid by Seller to deliver each Liquefaction Train to the Delivery Point (“Duties”) or the physical transportation costs set forth in Appendix K (Transportation Costs), exclusive of insurance costs and taxes associated with physical transportation costs other than Duties for each such Liquefaction Train (“Transportation Costs”). Buyer shall reimburse Seller for all reasonable, documented out-of-pocket Duties and Transportation Costs incurred by Seller, plus a fixed fee of [***], payable in accordance with Appendix B (Pricing; Payment Terms & Cancellation Schedule). The Contract Price does not include any Buyer Taxes. Transportation Costs, inclusive of the fixed fee, shall not exceed in the aggregate an amount equal to the sum of [***], provided that Seller has made commercially reasonable efforts to obtain competitive transportation pricing terms and to minimize transportation costs. When the amount of Transportation Costs forecast by Seller reaches [***] of the not to exceed amount of Transportation Costs amount set forth above and Seller reasonably estimates that the aggregate Transportation Costs may exceed such not to exceed amount of Transportation Costs, Seller shall notify Buyer and provide an estimate of the remaining Transportation Costs anticipated to complete the deliveries under this Agreement. Buyer will reasonably consider an adjustment to the not to exceed Transportation Costs; provided that any such increase in the Transportation Costs shall be mutually agreed in a Change Order to this Agreement. Buyer hereby agrees to pay the Contract Price to Seller upon completion of the relevant Payment Milestones in accordance with the payment schedule (the “Payment Schedule”) set forth in Appendix B (Pricing; Payment Terms & Cancellation Schedule), in consideration for the performance by Seller of its related obligations under the Agreement.

B. The Contract Price shall be adjusted by an amount equal to the sum of (a) an amount reflecting changes in labor and commodities indices calculated in accordance with Part 1 of Appendix M (Contract Price Adjustments) and (b) a foreign exchange adjustment calculated in accordance with Part 2 of Appendix M (Contract Price Adjustments) between the Effective Date and the date of issuance of LNTP (or the date of issuance of FNTP in the event LNTP is not issued). The adjustments described in this paragraph shall be mutually agreed upon by the Parties in a Change Order as soon as reasonably practicable following issuance of LNTP (or if LNTP is not issued, following the issuance of FNTP for) and availability of Index 1 set forth in Part 1 of Appendix M (Contract Price Adjustments).

 

A-29


C. In the event that LNTP is issued and FNTP is not issued within [***] Days following the issuance of LNTP, then the Contract Price shall be adjusted further by an amount equal to the sum of (a) an amount reflecting changes in labor and commodities indices calculated in accordance with Part 3 of Appendix M (Contract Price Adjustments) and (b) a foreign exchange adjustment calculated in accordance with Part 4 of Appendix M (Contract Price Adjustments) between the date that is [***] Days after issuance of LNTP and date of issuance of FNTP. The adjustments described in this paragraph shall be mutually agreed upon by the Parties in a Change Order as soon as reasonably practicable following issuance of FNTP and availability of Index 1 set forth in Part 3 of Appendix M (Contract Price Adjustments).

D. Payment of undisputed amounts of the Contract Price owed to Seller shall be made by Buyer thirty (30) Days from Buyer’s receipt of an invoice from Seller following completion of the relevant Payment Milestone(s) and receipt of all the relevant documentation, in accordance with the Agreement, and shall be remitted by wire transfer to the following account: [***]

 

7.2

Currency

Except as otherwise provided in the Agreement, payment shall be made by Buyer in Dollars, upon the completion of the individual Payment Milestones as set out in the Agreement and after Buyer’s receipt of an invoice for such Payment Milestones, reasonable evidence of the completion of such Payment Milestones, Lien waiver and releases in accordance with Clause 7.6, and other specified documentation required under the Agreement.

 

A-30


7.3

Late Payments

Any undisputed amounts due and unpaid by either Party to the other Party shall bear interest commencing when such payment is due at a rate equal to the lesser of (a) [***] above the per annum Prime Rate reported daily in The Wall Street Journal, or (b) the maximum rate permitted by applicable Law, on all amounts not timely paid in accordance with the Agreement. The payment of interest is in addition, and not in lieu, of a Party’s right to suspend its performance or terminate the Agreement, as provided for under the Agreement.

 

7.4

Payment of Subcontractors

Seller shall pay each Subcontractor, save for disputes between Seller and any Subcontractor, the amount to which Subcontractor is entitled in accordance with the terms and conditions of the Agreement between Seller and such Subcontractor.

 

7.5

Set Off Rights

Each Party shall have the right at any time or from time to time, to set off against any amount due to the other Party under the Agreement any amount due from the other Party under the Agreement, including any amounts due because of breach of the Agreement. Buyer may, after written notice to Seller, withhold payment on an invoice or a portion thereof in the event of a failure of Seller to perform the Payment Milestone related to the payment being requested under such invoice, until such time as such Payment Milestone has been completed by Seller in accordance with the provisions of the Agreement. The written notice to Seller shall reasonably describe the failure of Seller and requirements necessary under the Agreement to complete the Payment Milestone.

 

7.6

Invoice Documentation

As a condition precedent to the obligation of Buyer to make each payment under the Agreement, Seller shall deliver with each invoice for each payment, a partial Lien waiver and release in the form of Appendix J-1 (Seller Form of Partial Lien Waiver and Release) in exchange for the current payment, and a partial Lien waiver and release in the form of Appendix J-3 (Subcontractor Form of Partial Lien Waiver and Release) from each Subcontractor; provided however, if such invoice is the invoice for the final payment under the Agreement, Seller shall be obligated to provide Buyer a final Lien waiver and release in the form of Appendix J-2 (Seller Form of Final Lien Waiver and Release), in exchange for the final payment, and a final Lien waiver and release in the form of Appendix J-4 (Subcontractor Form of Final Lien Waiver and Release) from each such Subcontractor, in exchange for the final payment. In addition to the final Lien waivers and releases from each Subcontractor, Seller shall provide, with such final invoice, an affidavit setting forth: (a) all amounts paid to each Subcontractor; (b) all amounts owed to each Subcontractor, if any; and (c) any amounts in dispute under any subcontract.

 

A-31


7.7

No Liens

To the extent that Buyer has timely paid Seller under the Agreement, Seller shall (a) not directly or indirectly create, incur, assume, or suffer to be created by it or any Subcontractor, employee, laborer, materialman, or other supplier of goods or services any Liens on or in respect of a Liquefaction Train, the Site, the Facility or any part thereof or interest therein, or against any party, and (b) promptly pay and/or discharge of record any Lien or other charges that, if unpaid, might be or become a Lien on a Liquefaction Train, the Site, the Facility or any part thereof or interest therein. Seller shall pay when due all amounts payable for labor and materials furnished in connection with the Agreement to prevent any Lien or other claim in respect of such labor and materials from arising. Seller shall immediately notify Buyer of the assertion of any Lien on a Liquefaction Train, the Site, the Facility or any part thereof or interest therein. Upon the failure of Seller to promptly pay, discharge, or provide security reasonably acceptable to Buyer for any Lien on a Liquefaction Train, the Site, the Facility or any part thereof or interest therein in respect of which Seller has been timely paid in accordance with the Agreement, within ten (10) Working Days of notice of the existence thereof from any source, Buyer may, but shall not be obligated to, pay or discharge such Lien and, upon the payment or discharge thereof, shall be entitled to immediately recover from Seller the amount thereof together with expenses incurred by it in connection with such payment or discharge or to set off all such amounts against any such sums owed by Buyer to Seller under the Agreement.

 

7.8

Buyer Credit Support

Within thirty (30) Days of the Effective Date, Buyer will provide a Buyer Parent Company Guarantee substantially in the form of Appendix D (Form of Buyer Parent Company Guarantee) issued by Buyer’s parent company in favor of Seller and covering Buyer’s payment obligations under the Agreement. The initial Buyer Parent Company Guarantee shall remain valid until the earlier of (i) the assignment of the Agreement to the EPC Contractor in accordance with Clause 4 or (ii) Financial Closing, at which time the Buyer Parent Company Guarantee shall be of no further force and effect and Seller shall return the original Buyer Parent Company Guarantee to Buyer. If the Agreement is assigned by Owner to the EPC Contractor, the EPC Contractor (in its capacity as Buyer) will provide a Buyer Parent Company Guarantee substantially in the form of Appendix D (Form of Buyer Parent Company Guarantee) issued by the EPC Contractor’s parent company in favor of Seller and up to an amount equal to the Contract Price, which Buyer Parent Company Guarantee shall remain valid until receipt by Seller of the final payment of the Contract Price.

 

7.9

Seller Credit Support

Within thirty (30) Days of the Effective Date the Agreement, Seller shall provide a Seller Parent Company Guarantee substantially in the form of Appendix H (Form of Seller Parent Company Guarantee) issued by Seller’s Guarantor in favor of Buyer and covering Seller’s obligations under the Agreement.

 

A-32


7.10

Payment Not Acceptance

No partial or final payment made by Buyer shall be construed as a waiver of any breach hereof by Seller or as an acceptance of defective portions of the performance by Seller hereunder or of any of the performance of Seller’s obligations hereunder that does not strictly comply with all requirements of the Agreement.

 

8.

TAXES AND DUTIES

 

8.1

Seller Taxes; Buyer Taxes

Seller shall be responsible for and shall pay all Seller Taxes. Buyer shall be responsible for and shall pay all Buyer Taxes (or reimburse Seller for Buyer Taxes in the event Seller is required to remit any Buyer Taxes directly to taxing authorities). If Buyer deducts or withholds Seller Taxes from the Contract Price, for each deducted or withheld amount of Seller Taxes, Buyer shall provide Seller, within thirty (30) Days from payment of Seller Taxes, with the official receipt issued by the appropriate Governmental Authority to which Seller Taxes have been paid or an alternative document acceptable to the relevant tax authorities. In respect of taxes to be withheld, if any, Buyer shall comply with any applicable bilateral conventions against double taxation. If Buyer requires tax residence certificates from Seller to apply an exempted or reduced tax regime, Seller shall submit the appropriate certificates, upon Buyer’s written request. If Buyer, under the applicable Laws of any country other than Seller’s country of incorporation, deducts or withholds Seller Taxes, Buyer shall pay additional amounts to Seller so that Seller receives the full amount of the Contract Price, as though no such Seller Taxes had been deducted or withheld.

 

8.2

Exemptions

If either Party benefits from any tax, fee or Duty exemption (a “Benefitted Party”) applicable to the other Party or its Subcontractors (the “Other Party”), such Benefitted Party agrees to provide the Other Party, without charge, before invoicing, or before any other relevant event, documentation acceptable to supporting the tax or customs authorities supporting the exemption, together with instructions for the Other Party on the procedure for the exemption. Pursuant to state Law, certain tax and incentive programs are available to qualifying manufacturers in certain circumstances, including the Louisiana Quality Jobs Program, Enterprise Zone Program, and the Manufacturing Machinery and Equipment sales tax exclusion (collectively, the “Rebatable Louisiana Sales and Use Tax”). Owner has not determined which, if any, of these programs it will pursue. Seller shall cooperate with and assist Buyer and Owner and any designated tax and incentive consultant, and shall require Subcontractors to cooperate with and assist Buyer and Owner and any designated tax and incentive consultant, in obtaining tax and incentive benefits under these and any other available programs. Such assistance may include, but is not limited to, documenting purchase transactions, providing reports and supporting documents required to be submitted to obtain the tax and incentive benefits, and acting as agent for Owner in connection with the purchase of manufacturing machinery and equipment. If the determination of the proper amount of such Rebatable Louisiana Sales and Use Tax assessed on the Seller work is dependent upon knowing the actual cost incurred by Seller or its Subcontractors for the compensation of such Seller work, that portion of the audit

 

A-33


devoted to reviewing the actual cost incurred by Seller or its Subcontractors for such Seller work shall be performed by Buyer or Owner’s tax consultant, which shall be retained by Buyer or Owner at Owner’s sole expense. The Parties agree that (unless the amount of Rebatable Louisiana Sales and Use Tax properly payable for the Seller work is subject to audit, litigation, arbitration, subpoena or summons issued by a Governmental Authority) such tax consultant shall not disclose to Buyer or Owner the actual cost incurred by Seller or its Subcontractors for such work, but the Parties agree that such tax consultant may report to Buyer or Owner the proper Rebatable Louisiana Sales and Use Taxes properly payable under applicable Law. No access to documents shall be granted to Buyer or Owner’s tax consultant until such tax consultant has signed a confidentiality agreement with Seller and any applicable Subcontractor with terms customary in the audit industry for audits of this kind.

 

8.3

No Taxes Included

The Contract Price does not include any Buyer Taxes. Therefore if any Buyer Taxes are required to be collected by Seller, such Buyer Taxes will be added to the Contract Price. For Country sales and use tax, and in other jurisdictions where applicable, Buyer may report or remit sales taxes or similar taxes directly if Buyer timely provides a direct pay or exemption certificate to Seller.

 

8.4

Exemptions for Steel and Aluminum Imports

Seller shall provide all reasonably requested support and assistance to Owner and Buyer related to such filings (including any joint filings by Owner and Seller or its Affiliates) or deliverables that are necessary or appropriate to request an exclusion or exemption from the remedies instituted in Presidential Proclamations Adjusting Imports of Steel Into the United States and Adjusting Imports of Aluminum Into the United States under Section 232 of the Trade Expansion Act of 1962 or similar tariff measures; although Seller does not guarantee that it will achieve any particular results related to Seller’s support so provided. Such assistance may include, but is not limited to, documenting purchase transactions and providing reports and supporting documents required to be submitted to obtain the exclusion or exemption. If and to the extent the same would (to Seller’s knowledge) reasonably be expected to result in Buyer becoming liable hereunder for the payment of additional amounts in relation to tariffs or Duties, Seller shall consult with Buyer in good faith in relation to the selection of an alternative Approved Subcontractor not located in Asia.

 

9.

DELIVERY, TITLE TRANSFER, RISK OF LOSS, STORAGE

 

9.1

Delivery

Seller shall deliver equipment for each Liquefaction Train DDP the marine offloading facility(ies) adjacent to the Site as designated by Buyer to Seller for the items to be delivered by ocean vessel or barge (Incoterms 2020) and DDP the Site for the items to be delivered by truck (Incoterms 2020) (collectively, the “Delivery Point”). Except for those

 

A-34


obligations expressly set forth in the applicable Incoterms 2020 or as specifically provided under the Agreement, Seller shall not be liable in any claim asserted by Buyer with respect to delivery of the Liquefaction Trains beyond the Delivery Point. The date of delivery for each Liquefaction Train is the date on which such Liquefaction Train in its entirety is delivered in accordance with this Clause 9.1 per the Incoterms to the Delivery Point, or if applicable, to a transshipment facility, as shall be directed by Buyer to Seller from time to time and set forth in a Change Order. For the avoidance of doubt, delivery of an individual Liquefaction Train for purposes of the Agreement shall occur only when Seller has complied with all of its delivery obligations hereunder for that individual Liquefaction Train in its entirety. Except as otherwise provided in the Project Schedule or authorized in writing by Buyer, Seller shall not deliver the Liquefaction Trains (as provided in the Project Schedule) to the Delivery Point in each case more than [***] prior to the last day on which Buyer, in each case, would be entitled to payment of a bonus pursuant to Clause 6.7. Upon delivery, Buyer shall unload delivered items within a reasonable time, and for all ocean vessel/barge shipments no later than [***] from delivery.

 

9.2

Seller Replacement of Non-Conforming Items

If after delivery to the Delivery Point, Buyer discovers any item of a Liquefaction Train that has been damaged prior to delivery or that fails to conform with the requirements of the Agreement, then after receiving written notification of such non-conformance, the Seller shall promptly repair or replace such item or items, at Seller’s sole cost and expense in accordance with Clause 17.

 

9.3

Title; Risk of Loss

Title to each item of the Liquefaction Train shall pass from the Seller to the Buyer as follows:

 

  (a)

for each such item shipped from within the United States, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9.4, upon the earlier of (i) when Seller makes such item available for shipment from the warehouse or from the manufacturer’s factory and (ii) payment by Buyer to Seller for such item;

 

  (b)

for each such item shipped from the European Union, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9.4, upon the earlier of (i) when such item has been cleared for export, or (ii) when such item departs from the territorial land, sea and overlying airspace of the country from which such item is shipped; and

 

  (c)

for each such item shipped from within any other country, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9.4, when such item departs from the territorial land, sea and overlying airspace of the country from which such item is shipped.

 

A-35


Seller shall maintain the risk of loss of each Liquefaction Train until such Liquefaction Train is delivered to the Delivery Point. Buyer shall only be responsible for risk of loss of each Liquefaction Train once such Liquefaction Train has been properly delivered to the Delivery Point.

 

9.4

Storage Locations

If any Liquefaction Train cannot be delivered to Buyer in accordance with the delivery terms herein due to Buyer’s request or any cause attributable to Buyer or its Affiliates and its or their officers, servants, agents, employees, sub-contractors, suppliers, and/or assigns, including transportation, staging, storage, or shipping service providers, upon notice to Buyer, Seller may ship such Liquefaction Train to a storage location mutually agreed to by Buyer and Seller; provided that Seller is not obligated to store or maintain any Liquefaction Train at Seller’s site past the Delivery Date for such Liquefaction Train. If such Liquefaction Trains are placed in a storage location pursuant to the preceding sentence of this Clause 9.4, the following conditions shall apply: (a) any amount of the Contract Price otherwise payable to Seller upon delivery to the Delivery Point shall be invoiced by Seller and payable by Buyer within thirty (30) Days of receipt by Buyer of such invoice and related documentation, including certification by Seller as to cause for storage; (b) all reasonable and documented incremental expenses incurred by Seller, such as for preparation for and placement into storage, handling, inspection, preservation, insurance, storage, removal charges and any taxes shall be reimbursed by Buyer upon submission of Seller’s invoices and related documentation, including evidence of such incremental expenses; and (c) upon receipt of notice from Buyer and payment of all undisputed amounts due under this Clause 9, Seller shall resume delivery of the Liquefaction Trains to the originally agreed Delivery Point (and any transportation costs or Duties incurred in the transportation of the Liquefaction Trains from storage to the Delivery Point shall not be subject to the limitation on Transportation Costs set forth in Clause 7.1). In the event the storage period extends for longer than [***], the Parties shall reconvene to agree on the schedule to reach delivery. To the extent shipment to storage of any of the Liquefaction Trains causes a delay in Seller’s schedule for delivery of the remaining Liquefaction Trains to be delivered hereunder, then Seller shall have the right to request a Change Order for adjustment of the Delivery Date for such remaining Liquefaction Trains.

 

10.

SELLER’S OBLIGATIONS

 

10.1

Compliance with Law

Seller shall, in performing its obligations under the Agreement, comply in all respects with all applicable professional standards, permits and Laws, rules, codes and regulations and the Liquefaction Train System shall be in full compliance with all applicable professional standards, permits and Laws, rules, codes and regulations. Seller shall perform its obligations hereunder in accordance with the Project Schedule. Seller shall only use qualified personnel to perform its obligations hereunder. Seller shall be responsible for obtaining all licenses, permits and approvals from all Governmental Authorities that are required for Seller to perform its obligations under the Agreement.

 

A-36


11.

BUYER’S OBLIGATIONS

 

11.1

Access to and Possession of the Site

Access to the Site, including the use of Owner’s rights of way and easements, shall be granted to Seller by Buyer, only to the extent necessary and for the sole purpose of Seller performing its obligations under the Agreement.

 

11.2

Access not exclusive

The access to the Site provided by Buyer shall not be exclusive to Seller.

 

11.3

Personnel for Acceptance Tests

When each Liquefaction Train or Liquefaction Train System is ready for any acceptance or testing that is required under Appendix C (Scope of Supply & Project Schedule), Owner and/or Buyer shall provide the normal operating and maintenance personnel under the technical direction and supervision of Seller pursuant to the Services Agreement for such testing. For the avoidance of doubt, Seller’s personnel shall never be deemed to be Buyer’s or Owner’s employees, and vice versa.

 

11.4

Electricity, Water and Gas

Buyer shall be responsible at its own costs for the provision of all utilities, including but not limited to electricity, natural gas and water (including drinking water) for activities necessary to be performed on Site. Buyer shall also be responsible for and bear the costs of all arrangements for connection, metering and distribution.

 

11.5.

Organization on Site

Seller shall cause its personnel and its Subcontractor’s personnel to observe and comply with all safety and security protocols of Buyer when such personnel are on the Site, provided that Seller has been made aware of such safety and security protocols requirements.

 

12.

DOCUMENTATION BY SELLER

 

12.1

Reports

Seller shall prepare and submit to Buyer at the appropriate time the progress reports as detailed in Appendix C (Scope of Supply & Project Schedule). Seller shall submit all such other information and reports in relation to the Liquefaction Train System as Buyer shall reasonably request from time to time.

 

A-37


12.2

Submission of Technical Documentation

Appendix C (Scope of Supply & Project Schedule) specifies which Technical Documentation is to be submitted to Buyer by Seller. Seller shall submit such Technical Documentation to Buyer within the time required in Appendix C (Scope of Supply & Project Schedule). The Technical Documentation is required to be provided by Seller to Buyer. Buyer may give comments on any Technical Documentation submitted within [***] of Buyer’s receipt thereof, unless otherwise mutually agreed by Buyer and Seller, and Seller shall make the appropriate revisions to such Technical Documentation. The Technical Documentation shall include Seller’s standard Operation and Maintenance Manuals and the functional descriptions, in sufficient detail, to enable competent personnel to operate, maintain and repair the Liquefaction Train System.

 

12.3

Errors in Technical Documentation

Seller shall be liable for any Costs incurred in correcting any discrepancies, errors or omissions in the Technical Documentation prepared by it or its Subcontractors or on their behalf.

 

13.

MACHINERY, EQUIPMENT, SPARE PARTS AND WORKMANSHIP

 

13.1

Manner of Execution

The Liquefaction Train System shall be manufactured in the manner set out herein, including Clause 5, and in Appendix C (Scope of Supply & Project Schedule).

 

13.2

Quality of Materials

The Liquefaction Train System shall be brand new and unused, and all parts and components thereof shall be brand new and unused, upon delivery and shall in any event be in accordance with the standards and other requirements set forth in the Agreement.

 

13.3

Spare Parts

Not later than [***] prior to the Delivery Date of the first Liquefaction Train under the Agreement, Seller shall deliver to Buyer a detailed list and pricing proposal for all Subcontractor and Seller-recommended spare parts for operating and maintaining the Liquefaction Train System (including components and systems of each such Liquefaction Train System) (“Spare Parts”). Within [***] thereafter, Buyer shall specify in writing (via a Change Order) which items on the list of Spare Parts it wishes to purchase and the time (in accordance with Seller’s proposal) when such items should be delivered to a location designated by Buyer. The amount due from Buyer to Seller in connection with Spare Parts shall be based on current market prices.

 

A-38


14.

TESTING AND RIGHT TO INSPECT DURING MANUFACTURING

 

14.1

Documents

Seller documents that are included as Deliverables in Appendix C (Scope of Supply & Project Schedule) and annotated with an “A”, including Technical Documentation, shall be submitted to Buyer for approval, in accordance with the Project Schedule. Such documents shall be submitted to Buyer in substantially complete packages for each Liquefaction Train to be delivered hereunder.

 

14.2

Inspection and testing during manufacturing

Each Buyer Inspection Party shall be entitled during the manufacturing of the Liquefaction Train System to inspect and examine the materials and workmanship in accordance with the inspection test plan to be mutually agreed upon in accordance with Appendix C (Scope of Supply & Project Schedule), to attend any scheduled test of the Liquefaction Train System (or major components thereof) on Seller’s premises during working hours, and to check the progress of manufacture of the Liquefaction Train System (or major items thereof) to be supplied under the Agreement during normal business hours. If components of the Liquefaction Train System are being manufactured on other premises, Seller shall, upon receipt of written request from Buyer or Owner, make commercially reasonable efforts to obtain for the Buyer Inspection Parties permission to inspect, examine and attend any test, provided that such inspection, examination or attendance of tests shall not delay the execution of the works (without prejudice to Clause 14.3). Such inspection, examination or attendance of tests, if made, shall not grant access to areas of Seller’s facilities not related to the execution of Seller’s obligations under Appendix C (Scope of Supply & Project Schedule) or where other work of a proprietary nature is being performed.

 

14.3

Dates for inspection and testing

 

  (a)

Each Buyer Inspection Party shall have the right to witness such activity of inspection or testing required in accordance with Appendix C (Scope of Supply & Project Schedule). Buyer and Owner each shall have the right to ask for additional witness points during the manufacturing of the Liquefaction Trains, subject to Seller’s right to request a Change Order for any adverse impact on the delivery of the Liquefaction Trains as a result of such additional witness points.

 

  (b)

The Parties shall agree (at least thirty (30) Days prior to the proposed date) on the date on, and the place at, which the Liquefaction Train System and/or portion(s)/module(s) will be ready for inspection and/or testing. Should any postponement become necessary, Seller shall provide written notification of the same at least three (3) Working Days prior to the originally scheduled date. Each of Buyer and Owner shall give Seller two (2) Working Days’ notice in writing of its intention to attend the tests, or ask for a postponement of not more than twenty-four (24) hours if required.

 

A-39


  (c)

Should Buyer or Owner not attend the tests at the place and on the date which Seller has stated in its notice, Seller may proceed with the tests and Seller shall forthwith forward to Buyer and/or Owner the test results together with supporting data and written notice of required corrections, if any, which notice will state each respect in which the equipment is not in conformance with the Agreement, and perform all such corrections to the equipment to ensure that the equipment complies with the Agreement.

 

  (d)

If Buyer or Owner decides, at receipt of the test results, that the test should be repeated in its presence (even though the test results, in the opinion of Seller, were satisfactory), all the consequences of such repeat test (additional Cost and delay suffered by Seller) shall be borne by Buyer, unless such repeat tests give results materially not in accordance with the Agreement, in which case they shall be borne by Seller. If, however, neither Buyer or Owner notifies Seller, within five (5) Working Days after receipt of the test results, that it has decided that the test should be repeated in its presence, Seller shall not be obliged to repeat such test.

 

  (e)

Seller shall provide at least ten (10) Days’ advance notification to Buyer or a third party, acting on Buyer’s behalf, of any inspection or test in accordance with the procedures set forth in Appendix E (Quality Assurance and Quality Control). Buyer and Owner shall have the right to add by written notice to Seller witness points and/or holding points, either for Buyer or Owner or any such third party.

 

14.4

General right to inspect during manufacturing

Each Buyer Inspection Party shall be entitled to inspect the Liquefaction Train System during Seller’s manufacturing at Seller’s facilities, during working hours after having given to Seller a reasonable notice. Any inspection of the Liquefaction Train System by any Buyer Inspection Party shall not release Seller from any obligation under the Agreement nor constitute an acceptance by Buyer or any other party of any portion of the Liquefaction Train System inspected or tested.

 

14.5

Certificate of testing

As and when the Liquefaction Train System shall have passed the factory acceptance testing referred to in Section 1.6 of Appendix C (Scope of Supply & Project Schedule) during the manufacturing (the “Factory Acceptance Tests”), Seller shall, within thirty (30) days following completion of any Factory Acceptance Test, whether such Factory Acceptance Test passed or failed, provide the factory report with all required supporting data (including any anomalies encountered during the Factory Acceptance Test), signed by Seller and the factory performing such Factory Acceptance Tests and deliver the same to Buyer. All reports and related documentation associated with the Factory Acceptance Tests shall be stored in the manufacturing data books prepared in accordance with Seller’s standard practice, and all such manufacturing data books will be finally delivered to Buyer in electronic form no later than ninety (90) Days after the final Delivery Date.

 

A-40


14.6

Failure on tests or inspection

If as a result of any inspection, examination or test of the Liquefaction Train System, Buyer or Owner, as the case may be, shall consider with reasonable justification that the Liquefaction Train System and/or portion(s)/module(s) contain any Defect or is not in accordance with the Agreement, Buyer or Owner, as the case may be, shall notify Seller accordingly stating in writing its objection and reasons therefore. Seller shall promptly investigate Buyer’s or Owner’s claim, and if a Defect is found to exist, Seller shall rework and reperform its obligations under Appendix C (Scope of Supply & Project Schedule) necessary to remedy the Defect and bring the results of Seller’s performance of its obligations under Appendix C (Scope of Supply & Project Schedule) back in conformance with the requirements of the Agreement. Thereafter, if a Defect in any component of a Liquefaction Train is discovered before the delivery of such Liquefaction Train to the Delivery Point, if requested by Buyer or Owner, as the case may be, the necessary tests not passed shall be repeated under the same terms and conditions, provided that all Costs resulting from the repetition of the tests shall be for Seller’s account.

 

14.7

Right to inspect by others

In exercising its rights to inspect the Liquefaction Train System and/or to attend any tests under the Agreement, each of Buyer and Owner shall, upon consent of Seller and at Buyer’s cost, be entitled to be accompanied by any Lenders, Lender’s Engineer, advisor(s) of Buyer, or any adjusters or insurers’ representatives, provided that such accompanying Persons may be first required by Seller to enter a separate non-disclosure agreement with Seller. Seller shall allow all such Persons the same rights of inspection and test attendance as are enjoyed by Buyer or Owner pursuant to the Agreement, whether or not such inspection or attendance is made with Buyer or Owner, provided that such Persons may be first required by Seller to enter a separate non-disclosure agreement with Seller.

 

15.

DELIVERY OF THE LIQUEFACTION TRAINS

 

15.1

Delivery

Unless Buyer shall otherwise direct, no Liquefaction Train shall be delivered except in accordance with the schedule of Delivery Dates in the Project Schedule.

 

15.2

Packing and Marking

The Liquefaction Train System and/or portion(s)/module(s) shall be packed in boxes/containers or packing/packaging in accordance with Seller’s standards set forth in Appendix C (Scope of Supply & Project Schedule).

 

A-41


15.3

Detailed specification and procedure

On or before ten (10) Days prior to the Delivery Date of a component of a Liquefaction Train, Seller shall prepare and submit to Buyer, for information and approval, the detailed specification of packing and marking, specify the type and number of documents to be prepared and transmitted, with the form for each of them, all in accordance with the Agreement. Not less than ninety (90) Days prior to the first Delivery Date, the Parties shall meet and discuss the shipping procedures, including marking, cargo list preservation, preservation requirements and other related matters. With respect to equipment identified by either Party as suitable for direct delivery to or offloading at the Delivery Point, Seller shall consult with Buyer in advance of vessel reservation, and the Parties shall mutually agree on reasonably acceptable selection criteria with respect to the vessels to be used for such direct deliveries or offloading.

 

15.4

Warranty of ownership

Seller warrants and guarantees title to the Liquefaction Train System provided under the Agreement, and Seller warrants and guarantees that title and ownership thereto shall pass to and vest in Buyer, as agreed in the Agreement, free and clear of any and all Liens.

 

16.

COMPLIANCE WITH LAWS, CODES AND STANDARDS

 

16.1

Contract Price Basis

The Contract Price is based on Seller’s design, manufacture, testing and delivery of the Liquefaction Train System pursuant to:

 

  (a)

Seller’s design criteria, manufacturing processes and procedures and quality assurance program;

 

  (b)

those industry specifications, codes and standards that are (i) identified in Appendix C (Scope of Supply & Project Schedule) or (ii) otherwise applicable to the Liquefaction Train System or Seller’s obligations under the Agreement;

 

  (c)

those Laws in effect as of the Effective Date, which are applicable to the Liquefaction Train System or Seller’s obligations under the Agreement; and

 

  (d)

the specifications and other requirements contained in the Agreement, including Appendix C (Scope of Supply & Project Schedule).

 

16.2

Export Controls

The Parties agree to comply with all applicable export control and economic sanctions Laws in the performance of the Agreement, including any restrictions or conditions regarding the export, re-export, or other transfer of the Deliverables under the Agreement that are in effect now or are hereafter imposed by the any Governmental Authority. Each Party shall be responsible for its own compliance with applicable export control and economic sanctions Laws with regards to their Affiliates, employees, facilities and activities. These restrictions and conditions include, but are not limited to, (a) restrictions and export licensing requirements governing the export, re-export, or other transfer to other

 

A-42


persons, entities, or countries of the Deliverables under the Agreement, (b) restrictions and export licensing requirements governing the export or other transfer of foreign-developed information that incorporates the Deliverables under the Agreement, (c) any applicable restrictions on the export, re-export, or other transfer of the Deliverables under the Agreement to countries and Persons that are subject to applicable sanctions, embargoes, or other prohibitions, and (d) any applicable restrictions on the export or other transfer of the direct product of technical data. Each Party shall notify the other Party in writing prior to transferring any commodity, software or technology that is: (i) controlled at a level greater than EAR99 or Anti-Terrorism controls under the Export Administration Regulations (“EAR”); or (ii) subject to the jurisdiction of an export control regime other than the EAR. Seller acknowledges that, in connection with the performance of the Agreement, the export and customs Laws and regulations of the Country apply to the furnishing and shipment of the Liquefaction Train System.

 

16.3

Nuclear Activity Restrictions

The Liquefaction Train System sold hereunder is not intended for application (and shall not be used) in connection with any nuclear installation or activity and Buyer warrants that it shall not use the Liquefaction Train System for such purposes, or permit others to use or permit others to use the Liquefaction Train System for any such purposes. If, in breach of the foregoing, any such use of the Liquefaction Train System sold hereunder occurs, Seller shall have no liability for any nuclear or other damage, injury or contamination, and Buyer shall indemnify Seller, its Affiliates and suppliers of every type and tier against any such liability, whether arising as a result of breach of contract, warranty, indemnity, tort (including negligence), strict liability or otherwise.

 

16.4

Required Authorizations

Notwithstanding any other provisions herein, Seller shall be responsible for timely obtaining of any required authorization, such as an import license, foreign exchange permit, work permit or any other authorization from a Governmental Authority that are required for Seller to perform its obligations under the Agreement.

 

16.5

Anti – Corruption

 

  (a)

Each Party represents, warrants and covenants to the other Party that neither the representing Party, nor any of its Affiliates (or any of their respective principals, partners or funding sources), is currently (i) a Person designated by the U.S. Department of Treasury’s Office of Foreign Assets Control as a “specially designated national or blocked person” (“SDN”) or similar status, (ii) a person otherwise identified by a government or legal authority as a person with whom the other Party is prohibited from transacting business; (iii) directly or indirectly owned or controlled by an SDN or the government of any country that is subject to an embargo by the government of the Country; or (iv) a Person acting on behalf of an SDN or a government of any country that is subject to an embargo by the government of the Country. Each Party agrees that it will notify the other Party in writing immediately upon the occurrence of any event that subsequently results in any of the designations set forth in this Clause 16.5(a).

 

A-43


  (b)

Each Party shall, in the performance of the Agreement, comply with all Laws, orders, directives, and regulations in effect on the Effective Date and as they may be amended from time to time that are applicable to such Party. Notwithstanding anything contained herein to the contrary, the Agreement shall not be interpreted or applied so as to require either Party to do, or to refrain from doing, anything that would constitute a violation of federal or state laws and regulations applicable to it, including the Foreign Corrupt Practices Act of 1977, 15 U.S.C. § 78dd-2, the OECD Anti-Bribery Convention, the U.K. Bribery Act of 2010, E.U. and E.U. member country anti-bribery and corruption laws, laws or regulations restricting participation in or compliance with certain foreign boycotts, directly or indirectly, as contained in the U.S. Export Administration Act of 1979, the U.S. Internal Revenue Code or any similar statute, regulation, order or convention binding on such Party, as each may be amended from time to time, and including implementing regulations promulgated pursuant thereto (collectively, the “Anti-Corruption Laws”). Without limiting the foregoing, each Party agrees on behalf of itself, its Affiliates and their respective directors, officers, employees, agents and contractors, not to pay any fees, commissions or rebates to any employee, officer or agent of the other Party or its Affiliates or their respective shareholders, or provide or cause to be provided to any of them any gifts or entertainment of significant cost or value in connection with the Agreement or in order to influence or induce any actions or inactions in connection with the commercial activities of the Parties in connection with the Agreement.

 

  (c)

Each Party represents, warrants and covenants with respect to itself and its Affiliates that (i) it and its Affiliates are being and have been operated in compliance in all material respects with the Anti-Corruption Laws, (ii) neither it nor any of its Affiliates has received any written notice or claim alleging any material violation under any of the Anti-Corruption Laws, and (iii) neither it nor any of its Affiliates, nor any of their respective directors, officers, or employees (or, to the best of the representing Party’s knowledge and belief, any partner, intermediary or other Person acting or purporting to act on behalf of such Party or any of its Affiliates) has knowingly directly or indirectly paid, offered, given, promised to pay or authorized the payment of any money or anything of value to (A) any candidate for public office, any past or present employee, director, officer, official, representative or agent of any government, government or legal authority, instrumentality, or any public international organization (“Government Official”), (B) any Person acting for or on behalf of any Government Official, or (C) any other Person at the suggestion, request, direction or for the benefit of any of the above-described Persons to obtain, retain or direct business or to obtain special concessions or pay for favorable treatment for business secured or for special concessions already obtained.

 

A-44


  (d)

Neither Seller, nor any of its Affiliates, directors, officers, employees or agents, shall use its relationship with Buyer to attempt to disguise the sources of illegally-obtained funds. Seller further represents and warrants that no such attempt of the sort described in this Clause 16.5(d) has been made prior to the Effective Date.

 

  (e)

Each Party shall keep all records necessary to confirm compliance with this Clause 16.5 for a period of five (5) years following the year for which such records apply. If a Party asserts that the other Party is not in compliance with this Clause 16.5, the asserting Party shall notify the other Party indicating the type of non-compliance asserted. After such notification, the asserting Party may cause an independent auditor to audit the records of the other Party in respect of the asserted non-compliance. The costs of any independent auditor under this Clause 16.5(e) shall be paid (i) by the audited Party, if such Party is determined not to be in compliance with this Clause 16.5 or (ii) by the asserting Party, if the other Party is determined to be in compliance with this Clause 16.5.

 

  (f)

Seller agrees to indemnify, defend, release and hold Buyer, Buyer’s Parties and its and their shareholders, directors, officers, employees, agents, consultants or representatives harmless from any penalties and fines assessed by government authorities arising out Seller’s breach of any or all of this Clause 16.5. Buyer agrees to indemnify, defend, release and hold Seller Parties harmless from any penalties and fines assessed by government authorities arising out Buyer’s breach of any or all of this Clause 16.5. Any breach of any of the representations, warranties and covenants in this Clause 16.5 shall be grounds for termination of the Agreement, and if Seller is the breaching Party, there shall be no further payments due to Seller upon termination.

 

17.

WARRANTY

 

17.1

Warranty; Warranty Period

 

  (a)

Seller warrants to Buyer that (i) each Liquefaction Train shall be (A) free from defects in material, workmanship and title and (B) designed, engineered and manufactured in accordance with applicable Laws, the specifications referenced in the Agreement and the other requirements of the Agreement, and (ii) the performance by Seller of its obligations under Appendix C (Scope of Supply & Project Schedule) shall be free from defects and performed in accordance with applicable Laws and the other requirements of the Agreement. Except as set forth in Clause 17.2, the “Warranty Period” for the warranties in this Clause 17.1 shall be the period starting on the date of Substantial Completion of the Liquefaction Train for the first Liquefaction Train and ending upon: (i) in respect of the first [***] Liquefaction Trains set forth in the Project Schedule, the earlier of (1) [***] after the date of Substantial Completion of the Liquefaction Train System, and (2) [***] from the date that Seller delivered the applicable Liquefaction Train to the Delivery Point, and (ii) in respect of the last [***] Liquefaction Trains set forth in the Project Schedule, the earlier of (1)

 

A-45


  [***] after the date of Substantial Completion of the Liquefaction Train System and (2) [***] from the date that Seller delivered the applicable Liquefaction Train to the Delivery Point, provided that Buyer and Seller shall enter into the Preservation Agreement, for any Liquefaction Trains that are shipped to storage, if the storage period is for a period greater than [***].

 

  (b)

Buyer may, from time to time during the Warranty Period, issue a Change Order (and Seller shall execute such Change Order) extending the Warranty Period for one (1) or more Liquefaction Trains for the number of months specified in such Change Order such total extension not to exceed [***]. Such Change Order shall increase the Contract Price by an amount equal to [***] per Month for each Month that the Warranty Period for [***] Liquefaction Trains is extended by Buyer pursuant to the preceding sentence.

 

17.2

Remedial Actions

 

  (a)

If a failure to meet any of the warranties set forth in Clause 17.1 appears within the Warranty Period, Buyer shall promptly notify Seller in writing and make the defective component available for correction/inspection within a commercially reasonably time period thereafter. Seller, at its expense, shall thereafter correct any Defect by: (i) re-performing the defective performance of its obligations under Appendix C (Scope of Supply & Project Schedule); and (ii) repairing or replacing the defective Liquefaction Train System(s) or components thereof. Seller shall not be responsible for material removal or replacement of systems, structures or other parts of the Facility to grant Seller access to the Liquefaction Train System. Any repair, replacement or re-performance by Seller hereunder shall extend the applicable Warranty Period on such repaired, replaced or re-performed component of the Liquefaction Train System for a period of [***], provided that in no event shall the Warranty Period extend beyond [***] from the date of Substantial Completion of the Liquefaction Train System. Such warranty extension is in lieu of and not in addition to the extension of the Warranty Period for Serial Defects contemplated in Clause 17.2(c).

 

  (b)

Seller shall not be liable for Defects that arise after the Warranty Period, as extended hereunder, has expired. The testing of any replaced or repaired parts of the Liquefaction Train System, equipment or components shall be performed in the same manner as originally contemplated under the Agreement, and Buyer shall be notified of and may be represented at all tests that may be made. Seller shall not be responsible for the removal or replacement of any systems, structures or other parts of Buyer’s facility, which were not provided by Seller, in order for Seller to gain access to the Liquefaction Train System.

 

A-46


  (c)

If, prior to the expiration of the Warranty Period, [***] of the same component of the Liquefaction Train System experience a Defect of an identical or nearly identical nature that causes or could reasonably be expected to cause an outage of a Liquefaction Train (herein, a “Serial Defect”), then Seller shall examine the cause of the Serial Defect and (i) undertake technical analysis of the underlying problem in order to determine (A) the root cause of such Serial Defect and (B) the repairs or replacements that may be required to avoid future occurrences of such Serial Defect, (ii) prepare and provide to Buyer and Owner a written report setting forth the results of such analysis, (iii) promptly redesign if necessary and repair or replace any Liquefaction Train, as necessary, and (iv) if such Serial Defect root cause requires redesign, repair or replacement of the defective component or Liquefaction Train, extend the Warranty Period for such redesigned, repaired or replaced component for an additional period of [***], all at no additional cost to Buyer or Owner. Such warranty extension for Serial Defects is in lieu of and not in addition to the extension of the Warranty Period contemplated in Clause 17.2(a).

 

  (d)

If Seller fails to commence the corrective work for any Defects, Serial Defects or damage within a reasonable period of time not to exceed [***] after receiving notification by Buyer or Owner regarding such Defect, Serial Defect or damage, Buyer or Owner, at their sole discretion, may (in addition to any other remedies that each of them have under the Agreement) proceed to commence to correct such Defect, Serial Defect or damage at Seller’s risk and expense and the Costs incurred by Buyer or Owner, as the case may be, in performing such corrective work shall be paid by Seller.

 

17.3

Warranty Conditions

Seller does not warrant the Liquefaction Train System or any repaired or replaced parts against normal wear and tear or from the involvement in an accident. The warranties and remedies set forth herein are further conditioned upon:

 

  (a)

the proper storage (to the extent it is the responsibility of Buyer or its Affiliates and its or their officers, servants, agents, employees, sub-contractors, suppliers, and/or assigns, including transportation, staging or storage, or shipping service providers), installation, operation, and maintenance of the Liquefaction Train System in conformance with the operation instruction and installation manuals (including revisions thereto) provided by Seller; and

 

  (b)

repair or modification of the Liquefaction Train System pursuant to Seller’s instructions or approval.

Seller does not warrant any equipment or services of others designated by Buyer where such equipment or services are not normally supplied by Seller.

 

A-47


17.4

Warranties Exclusive

[***]

THE PRECEDING PARAGRAPHS OF THIS CLAUSE 17 SET FORTH THE EXCLUSIVE REMEDIES FOR ALL CLAIMS BASED ON FAILURE OF OR DEFECT IN THE LIQUEFACTION TRAIN SYSTEM OR PERFORMANCE OF SELLER’S OBLIGATIONS UNDER APPENDIX C (SCOPE OF SUPPLY) PROVIDED UNDER THE AGREEMENT, WHETHER THE FAILURE OR DEFECT ARISES BEFORE OR DURING THE WARRANTY PERIOD AND WHETHER A CLAIM, HOWEVER INSTITUTED, IS BASED ON CONTRACT, INDEMNITY, WARRANTY, TORT/EXTRA-CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY OR OTHERWISE. THE FOREGOING WARRANTIES ARE EXCLUSIVE AND ARE IN LIEU OF ALL OTHER WARRANTIES, CONDITIONS AND GUARANTEES WHETHER WRITTEN, ORAL, IMPLIED OR STATUTORY. NO IMPLIED STATUTORY WARRANTY OR MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE SHALL APPLY.

 

18.

INTELLECTUAL PROPERTY

 

18.1

Work Product

Any concept, idea, product, process, technique, discovery, improvement, know-how, work of authorship (including without limitation documents, specifications, calculations, maps, sketches, notes, reports, data, models, samples, drawings, designs, videos and electronic software) or other information, including the Technical Documentation, in each case whether subject to copyright registration or patent protection or not, other than Seller Developed Intellectual Property, that was first conceived, reduced to practice or created by Seller or any of its employees or Subcontractors in the performance of its obligations hereunder and (a) was furnished by Seller to Buyer as a Deliverable under the Agreement or (b) is an improvement to or otherwise incorporates Buyer’s Background Intellectual Property or Buyer’s Developed Intellectual Property (collectively, “Work Product”) shall be the sole property of Buyer. Seller agrees to assign and hereby assigns to Buyer all rights, title and interest throughout the world in and to all Work Product, including all Intellectual Property therein.

 

18.2

Background Intellectual Property

As between the Parties, each Party exclusively owns all right, title, interest in the Background Intellectual Property created or acquired by it. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty-free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses to the rights granted to Buyer under this Clause 18.2 and to freely transfer the rights granted to Buyer under this Clause 18.2 to third parties, other than to Seller’s Competitors) [***]

 

A-48


Seller expressly reserves all other rights in Seller Background Intellectual Property. Buyer hereby grants to Seller and Seller’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights [***].

 

18.3

Seller Developed Intellectual Property

As between Seller and Buyer, all improvements to the Background Intellectual Property of Seller that are first conceived, reduced to practice or created by Seller or any of its employees or Subcontractors in the performance of Seller’s obligations under the Agreement (the “Seller Developed Intellectual Property”) shall be owned by Seller, subject to Buyer’s rights in any Background Intellectual Property of Buyer contained therein. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses and to freely transfer the rights granted to Buyer under this Clause 18.3 to third parties other than the Seller Competitors) [***]. Seller expressly reserves all other rights in Seller Developed Intellectual Property.

 

18.4

Buyer Developed Intellectual Property

As between Seller and Buyer, all improvements to the Background Intellectual Property of Buyer that are first conceived, reduced to practice or created by Buyer or any of its employees, contractors or consultants in the performance of Buyer’s obligations under the Agreement (the “Buyer Developed Intellectual Property”) shall be owned by Buyer, subject to Seller’s rights in any Background Intellectual Property of Seller contained therein.

 

18.5

Instruments of Service

All reports, design drawings, specifications, field data and notes, calculations, estimates and other documents prepared in the performance of Seller’s obligations under the Agreement by Seller or any of its employees or Subcontractors as instruments of service, other than any such items that are Work Product and other than any items that include Buyer Developed Intellectual Property and/or Buyer’s Background Intellectual Property (collectively, the “Instruments of Service”), shall remain Seller’s property. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights [***].

 

A-49


18.6

Outside Intellectual Property

(a) Seller shall not use any trade secret, invention, work of authorship, software, patent or protectable design conceived or developed by a party other than Buyer or Seller (collectively, the “Outside Intellectual Property”) in connection with the Agreement unless Seller has secured the rights to use such Outside Intellectual Property for the benefit of Buyer. To the extent Seller uses such Outside Intellectual Property in connection with the Agreement and to the extent that Seller has the legal and contractual right to do so, Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses to the rights granted to Buyer under this Clause 18.6 and to freely transfer the rights granted to Buyer under this Clause 18.6 to third parties) [***].

(b) Upon Buyer’s request, Seller agrees to provide, without any additional charge, a copy of the Exchanger Design and Rating native file for the dynamic simulation of the Liquefaction Train (the “EDR File”) generated by the supplier of the Cold Boxes. Subject to Clause 22, Buyer shall have the right to use the EDR File for the sole purpose of (i) [***], and (ii) [***]. Except for the use rights set forth herein, nothing in the Agreement is deemed to grant or transfer any Intellectual Property Rights in the EDR File to Buyer. The EDR File shall not be considered a Deliverable and shall be provided by Seller “AS IS” without warranties of any kind.

 

18.7

Restrictions on Use

Except to the extent required by applicable Law, copies of any Work Product, Seller Developed Intellectual Property or Instruments of Service shall not be released to any other party by Seller, or to any Seller Competitors, or used by Seller for any purpose that is unrelated to the Facility, except in response to a subpoena, court order or other legal process, or to the extent that the foregoing materials were already within the public domain or in the possession of third parties, without the prior written approval of Buyer, which Buyer may withhold in its sole and absolute discretion and excepting that the Parties agree that the restrictions on use in this Clause 18 shall not preclude Seller from using, and Buyer

 

A-50


specifically agrees, that Seller retains rights to use (including on subsequent projects or scopes of work with third parties) the Seller’s Know-How, Seller Developed Intellectual Property and Instruments of Service, but subject to the confidentiality obligations set forth in Clause 22. At the expiration or earlier termination of the Agreement, Seller shall promptly deliver to Buyer (but in any event, no later than thirty (30) Days from the date of such expiration or termination) all of the Work Product in all forms and formats including without limitation hard copies and electronic files on disks.

 

18.8

Notification and Indemnification

If either Party is made the subject of any Intellectual Property Claim, such Party shall promptly notify the other Party in writing. Buyer shall defend and indemnify Seller against those Intellectual Property Claims only to the extent that Seller’s allegedly infringing or misappropriating conduct is expressly requested in writing by Buyer. This indemnity shall not extend to any conduct of Seller which is discretionary to Seller. Seller shall defend, indemnify and hold the Buyer Parties harmless against any Losses arising from any Intellectual Property Claim. In no event shall Seller have such indemnity obligations for any Intellectual Property Claim arising from or in connection with any material modification by Buyer that was not authorized by Seller. Buyer shall (a) promptly notify Seller in writing of its receipt of such Intellectual Property Claim and (b) make no admission of liability and (c) not take any position materially adverse to Seller regarding such Intellectual Property Claim. Without limiting the foregoing, Seller shall, at its own expense and option, promptly, but in no event later than thirty (30) Days following the date of notice from Buyer (i) settle or defend the claim or any suit or proceeding and pay all damages and costs awarded in it against Buyer, (ii) procure for Buyer or reimburse Buyer for procuring, the right to continue using the deliverables from Seller’s performance of its obligations under the Agreement, including the infringing service, the Technical Documentation, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim, (iii) modify such infringing deliverables, including the Technical Documentation, service, materials, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim so that they become non-infringing or (iv) replace the infringing deliverables, including any Technical Documentation, service, materials, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim with non-infringing deliverables to the satisfaction of Buyer; provided that in no case shall Seller take any action which adversely affects Buyer’s continued use and enjoyment of the applicable service, materials, Work Product, or other Intellectual Property without the prior written consent of Buyer. Buyer’s acceptance of the materials, Deliverables, Work Product, and other equipment or any other component of Seller’s performance under the Agreement shall not be construed to relieve Seller of any obligation hereunder. The Buyer Parties agree to cooperate and assist Seller in the defense of any Intellectual Property Claims, at Seller’s cost. Any Buyer Party which seeks to settle any Intellectual Property Claim shall seek the prior approval of Seller, which approval shall not be unreasonably withheld, conditioned, or delayed, in respect of such settlement.

 

A-51


18.9

Seller Simulation Models

Upon Buyer’s request, Seller agrees to provide, if and when requested by Buyer, without any additional charge, one permit for permission based access to Seller’s web-based service that provides access to a copy of the Liquefaction Train transient simulation model created, conceived or developed by Seller or any of its employees or Subcontractors based on a Subcontractor proprietary software named [***] (the “BH-Transient Liquefaction Train Simulation Model”), and, subject to Clause 22, Seller hereby grants to Buyer and Buyer’s Affiliates a, royalty free, non-transferable, non-sublicensable, worldwide, fully paid-up, non-exclusive license [***]. The BH-Transient Liquefaction Train Simulation Model shall not be considered a Deliverable and shall be provided by Seller “AS IS” without warranties of any kind.

 

18.10

Survival

The provisions of Clause 18 shall survive the completion or early termination of the Agreement.

 

19.

INDEMNITY AND LIMITATION OF LIABILITY

 

19.1

Indemnification

 

  (a)

Seller shall indemnify, defend, release and hold harmless the Buyer Parties from any physical damage to property of third parties or injury to Persons, including death, to the extent resulting directly from the negligence or willful misconduct of Seller or its officers, servants, agents, employees, and/or assigns while engaged in activities relating to the Agreement. Buyer shall indemnify, defend, release and hold harmless the Seller Parties from any physical damage to property of third parties or injury to Persons, including death, to the extent resulting directly from the negligence or willful misconduct of Buyer, its officers, servants, agents, employees, and or assigns, while engaged in activities relating to the Agreement. In the event such damage or injury is caused by the joint or concurrent negligence of Seller and Buyer, the loss shall be borne by each Party in proportion to its negligence.

 

A-52


  (b)

For the purposes of this Clause 19.1 no portion of the Facility or the Site shall be considered third party property and Buyer and Owner release claims related to property damage to the Facility or the Site caused by Seller (and including those property damage claims caused by Seller’s negligence or willful misconduct); provided, however, Seller shall, to the extent directly caused by the negligence or willful misconduct of Seller, be responsible to Buyer and Owner (subject to the limitations of Clause 19.2 and Clause 19.3) for: [***], Seller shall reimburse Buyer and Owner (without duplication) for the deductible amounts related to the damage to the Facility or the Site.

 

19.2

Limit of Liability

EXCEPT, WITH RESPECT TO [***], THE TOTAL LIABILITY OF EACH PARTY FOR ALL CLAIMS OF ANY KIND, WHETHER IN CONTRACT, WARRANTY, INDEMNITY, TORT/EXTRA- CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY, OR OTHERWISE, ARISING OUT OF OR RELATING TO THE PERFORMANCE OR BREACH OF THE AGREEMENT OR USE OF THE LIQUEFACTION TRAIN SYSTEM, SHALL NOT EXCEED [***]. BUYER’S PAYMENT OF THE CONTRACT PRICE SHALL NOT COUNT TOWARDS BUYER’S CONTRACT PRICE LIMIT OF LIABILITY HEREUNDER. FURTHER, WITH RESPECT TO SELLER’S FAILURE TO ACHIEVE (1) EACH OF THE LIQUEFACTION TRAIN PERFORMANCE GUARANTEES AND (2) EACH OF THE LIQUEFACTION TRAIN SYSTEM PERFORMANCE GUARANTEES, BUYER AGREES, AFTER ANY TERMINATION OF THE AGREEMENT BY BUYER, NOT TO ASSERT ANY CLAIMS AGAINST SELLER FOR MONETARY DAMAGES IN EXCESS OF [***]. FOR THE AVOIDANCE OF DOUBT, SELLER’S OBLIGATIONS UNDER A CLAIM FOR SPECIFIC PERFORMANCE ARE NOT LIMITED BY THIS CLAUSE 19.2.

 

A-53


19.3

Waiver of Consequential Damages

IN NO EVENT, WHETHER AS A RESULT OF BREACH OF CONTRACT, WARRANTY, INDEMNITY, TORT/EXTRA CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY, OR OTHERWISE, SHALL EITHER PARTY OR ITS SUBCONTRACTORS OR SUPPLIERS BE LIABLE FOR LOSS OF PROFIT OR REVENUES, LOSS OF USE OF THE LIQUEFACTION TRAIN SYSTEM OR ANY ASSOCIATED EQUIPMENT, DOWNTIME COSTS, CLAIMS OF A PARTY’S CUSTOMERS FOR SUCH DAMAGES, OR FOR ANY SPECIAL, CONSEQUENTIAL, INCIDENTAL, INDIRECT OR EXEMPLARY DAMAGES. THE WAIVERS SET FORTH IN THIS CLAUSE 19.3 SHALL NOT APPLY TO LIQUIDATED DAMAGES OR ANY THIRD PARTY INDEMNIFICATION CLAIMS UNDER THE AGREEMENT, PROVIDED THAT EACH OF THE SELLER EXCLUDED PARTIES AND BUYER EXCLUDED PARTIES SHALL NOT BE DEEMED A THIRD PARTY FOR THE PURPOSES OF THIS CLAUSE 19.3.

 

19.4

Seller Protection from Third Parties

If Buyer is furnishing Seller’s Liquefaction Train System to a third party by contract or using Seller’s Liquefaction Train System at a facility owned by a third party, Buyer shall [***].

 

20.

DISPUTE RESOLUTION

 

20.1

Disputes

Any dispute, controversy or claim between the Parties that arises out of, under or in connection with the Agreement, including its interpretation, performance, enforcement, termination, validity or breach (each a “Dispute”) shall be subject to resolution under this Clause 20, which shall be the exclusive dispute resolution method for any such Dispute. A Party wishing to declare a Dispute shall deliver to the other Party a notice identifying the disputed issue (a “Notice of Dispute”). Following the delivery of a Notice of Dispute, the Parties shall attempt in good faith to resolve such Dispute promptly through negotiation. If the Dispute has not been resolved within thirty (30) Days after the date on which the Notice of Dispute was delivered, then any Party shall be permitted to submit such Dispute to binding arbitration in accordance with Clause 20.2.

 

20.2

Arbitration

Any Dispute that is not resolved pursuant to Clause 20.1 shall be exclusively and definitively resolved through final and binding arbitration conducted in accordance with the Rules of Arbitration of the International Chamber of Commerce (the “ICC Rules”), which (except as modified by this Clause 20.2) are deemed to be incorporated by reference into this Clause 20.2.

 

A-54


  (a)

The arbitration tribunal shall consist of three (3) arbitrators. One (1) arbitrator shall be appointed by Buyer, one (1) arbitrator shall be appointed by Seller, and the third arbitrator shall be selected by agreement of the first two (2) arbitrators. If either of the first two (2) appointments is not made within thirty (30) Days after the request for arbitration, or if the first two (2) arbitrators fail to agree on a third arbitrator within thirty (30) Days after the later of them has been appointed, the unfilled appointment will be made, at the request of either Party, by the ICC. No arbitrator appointed pursuant to this Clause 20.2(a) shall be an employee, agent, contractor, competitor or former employee, agent or contractor of, or have or have had any material interest (directly or indirectly) in the business of or in any Party or any of its Affiliates. Each arbitrator shall be knowledgeable with respect to engineering, procurement and construction contracts and shall be fluent in the English language.

 

  (b)

Unless the Parties agree in writing otherwise:

 

  (i)

the seat of arbitration shall be New York, New York, and the language to be used in the proceedings shall be English;

 

  (ii)

the arbitrators shall, by majority vote, render a written award stating the reasons for their award within three (3) Months after any hearing conducted has been concluded. The arbitral award may contain such orders (including orders for specific performance, setoff, other equitable relief or monetary damages) in respect of or affecting any of the Parties (and/or any direct loss or damage suffered by any of them), as such arbitrators determine to be appropriate in the circumstances; provided that, except as expressly permitted by the terms of the Agreement, the arbitrators shall not have the authority to award any indirect, consequential or punitive damages;

 

  (iii)

the Parties and the arbitral tribunal will ensure that the arbitration proceedings and any documents disclosed in such proceedings are kept strictly confidential; and

 

  (iv)

the responsibility for the costs of the arbitration will be determined by the arbitral tribunal.

 

  (c)

An arbitral award rendered in accordance with this Clause 20.2 shall be final and binding on the Parties. The Parties agree that any arbitral award made pursuant to this Clause 20.2 may be enforced against the Parties or their assets wherever they may be found and that a judgment upon the arbitral award may be entered (and any other applicable relief, including interlocutory relief, may be granted) in any court having jurisdiction on such matters, and subject to their respective obligations contained elsewhere in the Agreement, shall take all such actions as are necessary to give full and complete effect to the award which, in accordance with its terms, shall be binding upon and enforceable against them. The Parties may make an application to any court for the obtaining of any evidence (whether by discovery of documents, interrogatories, affidavits or testimony of witnesses or whatsoever), which the arbitrators direct shall be admitted in the arbitral proceedings.

 

A-55


  (d)

No Party shall be entitled to suspend its performance under the Agreement during the pendency of any Dispute or during the period during which any defaulting Party is attempting to remedy its non-performance of the Agreement within the periods prescribed therefor in Clause 28.

 

  (e)

Nothing contained in this Clause 20 shall be construed to prohibit any Party from making an application to any court of competent jurisdiction for an order of specific performance or for other injunctive or equitable relief as long as the arbitral tribunal contemplated in Clause 20.2 has not yet been formed.

 

20.3

No Consolidation

Unless the Parties otherwise agree, no dispute, controversy or claim hereunder shall be consolidated with any other arbitration proceeding involving any third party.

 

21.

GOVERNING LAW

The validity, construction and performance of the Agreement shall be governed by and construed in accordance with the laws of the State of New York, without regard to the conflict of law provisions thereof that would require the application of the laws of any other jurisdiction.

 

22.

CONFIDENTIALITY

 

22.1

Confidential Information

In connection with the Agreement, each Party (as to information disclosed, the “Disclosing Party”) may each provide the other Party (as to information received, the “Receiving Party”) with Confidential Information. “Confidential Information” means:

 

  (a)

all pricing for Liquefaction Train System;

 

  (b)

all information that is designated in writing as “confidential” or “proprietary” by Disclosing Party at the time of written disclosure, except Work Product; and

 

  (c)

all information that is orally designated as “confidential” or “proprietary” by Disclosing Party at the time of oral disclosure and is confirmed to be “confidential” or “proprietary” in writing within ten (10) Days after oral disclosure, except Work Product.

 

A-56


Any Confidential Information disclosed or revealed by the Disclosing Party shall remain the Disclosing Party’s property and the Receiving Party shall not use such Confidential Information for its own benefit or for the benefit of any third party nor shall the Receiving Party disclose to any third party any such Confidential Information disclosed or revealed to it by the Disclosing Party, except as permitted under the Agreement. The Receiving Party shall take every reasonable precaution to protect the confidentiality of Confidential Information.

The obligations of this Clause 22.1 shall not apply as to any portion of the Confidential Information that:

 

  (i)

is or becomes generally available to the public other than from disclosure by Receiving Party, its representatives or its Affiliates;

 

  (ii)

is or becomes available to Receiving Party or its representatives or Affiliates on a non-confidential basis from a source other than Disclosing Party when the source is not, to the best of Receiving Party’s knowledge, subject to a confidentiality obligation to Disclosing Party;

 

  (iii)

is independently developed by Receiving Party, its representatives or Affiliates, without reference to the Confidential Information;

 

  (iv)

is required to be disclosed by Law, a valid legal process or a Governmental Authority;

 

  (v)

is approved for disclosure in writing by an authorized representative of Disclosing Party;

 

  (vi)

is disclosed by Seller to its Affiliates and each of their agents, advisors, employees, consultants, contractors, officers, directors and representatives (collectively, the “Seller’s Representatives”) to the extent necessary to evaluate the Facility and provided that each such Seller’s Representative is advised of the confidential nature of such Confidential Information and agrees to be bound by provisions consistent with the provisions of the Agreement or is bound by professional obligations of confidentiality;

 

  (vii)

is disclosed by Buyer to Owner, Owner’s Affiliates and each of their agents, advisors, employees, consultants, contractors, officers, directors, representatives, existing or potential investors, Lenders and existing or potential offtakers (and their respective consultants, advisors and agents) (collectively, the “Buyer’s Representatives”) to the extent necessary to evaluate the Facility and provided that each such Buyer’s Representative is advised of the confidential nature of such Confidential Information and agrees to be bound by provisions consistent with the provisions of the Agreement or is bound by professional obligations of confidentiality; or

 

  (viii)

is disclosed by Buyer or Owner to any Governmental Authority in connection with the Facility.

 

A-57


22.2

Restrictions on Use

Receiving Party agrees:

 

  (a)

to use the Confidential Information only as permitted under the Agreement;

 

  (b)

to take reasonable measures to prevent disclosure of the Confidential Information, except as permitted under the Agreement; and

 

  (c)

not to disclose the Confidential Information to any Person other than its Representatives.

Any Confidential Information disclosed or revealed by the Disclosing Party shall remain the Disclosing Party’s property. Receiving Party agrees to obtain a commitment from any recipient of Confidential Information to comply with the terms of this Clause 22. Confidential Information shall not be reproduced without Disclosing Party’s written consent, and upon expiration or termination of the Agreement, the Receiving Party shall return to the Disclosing Party all Confidential Information in its possession or control, except to the extent that the Agreement entitles Receiving Party to retain the Confidential Information; provided, however, that the return of such Confidential Information shall not affect the license rights granted to Buyer pursuant to Clause 18.

 

22.3

Disclosure

If Receiving Party or any of its Affiliates or Representatives is required to disclose any Confidential Information pursuant to Clause 22.1(iv), the Receiving Party agrees to provide Disclosing Party with prompt written notice to permit Disclosing Party to seek an appropriate protective order or agency decision or to waive compliance by Receiving Party with the provisions of this Clause 22. In the event that efforts to secure confidential treatment are unsuccessful, Receiving Party may, to the extent lawful, revise the Confidential Information to make it non-proprietary or to minimize the loss of its proprietary value.

 

22.4

No License

Nothing in Clause 22 grants Receiving Party any license to any invention, patent, trademark or copyright now or later owned or controlled by Disclosing Party.

 

22.5

Available Remedies

Each Party acknowledges that money damages would not be a sufficient remedy for a breach of this Clause 22. The Parties acknowledge that any violation of this Clause 22 by the Receiving Party may cause the Disclosing Party irreparable harm that could not be fully remedied by monetary damages. Accordingly, if it appears that the Receiving Party has disclosed (or has threatened to disclose) Confidential Information in violation of the

 

A-58


Agreement, the Disclosing Party shall have the right, in addition to, and not in lieu of, monetary damages or any other legal or equitable remedy available to it, to seek injunctive or other equitable relief from a court of competent jurisdiction, without the necessity of proving damages or posting any bond, as may be necessary to prevent any such violation.

 

22.6

No Public Announcements

Neither Party shall make any public announcement about the Agreement or related documents, including its existence, without prior written approval of the other Party.

 

22.7

Survival

As to any individual item of Confidential Information, the restrictions of this Clause 22 shall expire upon the earlier of five (5) years following the date of disclosure or three (3) years following termination or expiration of the Agreement, except with respect to Confidential Information that the Disclosing Party protects as a trade secret, for which the obligations set forth in this Clause 22 shall remain in effect as long as such Confidential Information remains a trade secret.

 

23.

INSURANCE

 

23.1.

Seller Coverage Requirements.

Seller shall secure, pay for, and provide, at no additional cost or expense to Buyer or Owner, the following insurance coverages during the term of the Agreement:

(a) Workers’ Compensation Insurance with statutory limits in accordance with all applicable state, federal and maritime laws, and Employer’s Liability Insurance with minimum limits of $[***] per accident/occurrence for bodily injury per accident, each employee for disease. No “alternative” forms of coverage will be permitted. If optional under state legal requirements, insurance must cover all employees regardless.

(b) Commercial General Liability Insurance with minimum limits of $[***] combined single limit per occurrence and $[***] in the aggregate, including, but not limited to, coverage for bodily injury liability, property damage liability, products liability including completed operations, personal/advertising injury liability, and sudden and accidental pollution. Buyer and Owner must be named as additional insured.

(c) Automobile Liability Insurance with minimum limits of $[***] combined single limit per accident/occurrence for bodily injury liability and property damage liability, including, but not limited to, coverage for all owned, hired and non-owned vehicles or automotive equipment used by or for Seller and including coverage for contractual liability for those liabilities assumed by the Contractor herein.

(d) Umbrella or Excess Liability Insurance with minimum limits of $[***] per accident/occurrence and in the aggregate in excess of the primary liability coverage and limits contained herein (except Workers’ Compensation Insurance, Property Insurance, and Professional Liability Insurance). This excess coverage shall be no less restrictive than the scope of the coverage afforded by the primary coverage outlined herein and shall have the same inception and expiration dates as Commercial General Liability Insurance.

 

A-59


(e) Professional Liability Insurance, with minimum limits of $[***] combined single limit per occurrence and in the annual aggregate, covering liability stemming from errors or omissions or rendering or failing to render any professional services as required under the Agreement and, as such insurance is provided on a “claims made” basis, (1) with a retroactive date no later than the commencement date of services to be performed under the Agreement, and (2) this insurance is to remain in force or be maintained for at least three years following the completion of services under the Agreement.

(f) Cyber Liability Insurance with minimum limits of $[***] per occurrence and in the aggregate, coverage including, but not be limited to, infringement of intellectual property liability such as copyright, trademark, trade dress, invasion of privacy violations, information theft, damage to or destruction of electronic information, release of private information, alteration of data, extortion and network security. Coverage shall also include breach response costs and regulatory fines and penalties, as well as credit monitoring expenses with limits sufficient to respond to these obligations.

(g) Marine Liability Insurance for all vessels owned, operated, chartered, or brokered by or for Seller in connection with its work or services under the Agreement, Seller shall carry or require the owner or operator of such vessels to carry:

 

  i.

Hull Insurance for replacement cost value of each vessel.

 

  ii.

Protection and Indemnity Insurance with minimum limits of $[***] combined single limit per occurrence to cover liabilities arising out of the ownership, operation and use of any vessel including, but not limited to, coverage for contractual liability for those liabilities assumed by Seller herein, including coverage for crew and personnel on such vessels, with no exclusion for activities arising from the use of remote operated vehicles and submarines and diving operations (if these operations are to be performed under the Agreement), and including Collision and Tower’s Liability, Cargo Legal Liability (to the extent applicable), and coverage for liabilities for the removal of wreck or debris as compulsory under statute or where such wreck or debris interferes with the operations of Owner or third parties. Insurers shall waive any right to limit liability to the value of the vessel, but only with respect to indemnitees, only to the extent of the liabilities assumed, and, to the extent of the liabilities assumed, the policies (including any excess policies) shall be endorsed to provide full coverage to indemnitees, as additional insured, without regard to whether liability has been incurred “as owner” of the vessel and the phrase “as owner of vessel named herein” and all similar phrases purporting to limit the insurer’s liability to that of an owner shall be deleted. This insurance shall include

 

A-60


coverage for pollution and cleanup liability on a sudden and accidental basis and, where applicable, insurance shall include coverage as provided under the latest Form SP-23 and must satisfy minimum coverage limit requirements under applicable law and include coverage for crew and personnel on such vessels, with no exclusion for activities arising from the use of remote operated vehicles and submarines and diving operations (if these operations are to be performed under the Agreement).

 

  iii.

Charterer’s Legal Liability Insurance, on a form equivalent to the IG Club United Kingdom Mutual Assurance Association (Bermuda) Ltd. standard form of certificate and/or under their club rules for charterers’ risks, with minimum limits of $[***] combined single limit per occurrence to cover liabilities arising out of operation and use of any time or voyage chartered vessel including coverage for contractual liability for those liabilities assumed by Seller herein.

 

  iv.

The insurance listed in (i), (ii) and (iii) above shall provide that seaworthiness of vessels used to perform services under the Agreement is accepted by insurers (or that insurers shall waive in favor of indemnitees, the vessel owner’s and/or Seller’s warranty of seaworthiness).

(h) To the extent of the liabilities assumed by Seller herein and to the extent permitted by applicable law, all insurance policies obtained by Seller that provide liability or property coverage related to the services or work under the Agreement shall be endorsed to provide that:

 

  i.

Seller’s insurers waive their right of subrogation, excluding Professional Liability, (equitable or by assignment, express or implied, loan receipt or otherwise) against Company.

 

  ii.

Seller’s insurers shall name Buyer, Owner and any other person designated by the Buyer as additional insureds, to the extent allowed by law (except for Workers’ Compensation Insurance, Property Insurance, and Professional Liability Insurance).

 

  iii.

such insurance coverage is primary and non-contributory to any other insurance coverage afforded to Buyer or Owner.

 

  iv.

the policy contains cross-liability coverage as provided under standard ISO forms’ separation of insureds clause.

(i) the inception of the Agreement, annually thereafter, and whenever requested, Seller shall furnish insurance certificates to evidence the insurance required herein. However, receipt of such certificates and endorsements shall not relieve Seller of any insurance obligations herein. Furthermore, receipt of such certificates or failure to object to same shall not be deemed to constitute a waiver of any of the insurance requirements required to be carried by Seller herein. Seller’s insurance shall be carried with insurance companies satisfactory to Buyer (A.M. Best A- VII or better or equivalent) and either Seller, its insurer, and/or its agent. All self-insured amounts, deductible amounts, premiums, franchise amounts or other charges due with respect to each Seller’s required insurance herein shall be the sole obligation of said Seller. Maintaining the prescribed insurance shall not relieve Seller of any other obligation under the Agreement. Failure of Seller to obtain and maintain the required insurance will constitute a breach of the Agreement.

 

A-61


23.2

Additional Requirements.

(a) All commercial general liability and automobile liability insurance coverage shall be written on an occurrence-based form.

(b) An original certificate of insurance shall be delivered to the Buyer within five (5) Days of the Effective Date, prior to commencement of any work or prior to the payment of any amounts by the Buyer hereunder, whichever occurs first. The certificate of insurance shall evidence insurance coverage at least in the minimum limits, or as may be further increased in connection with the requirements of the Agreement. Seller, its insurer, and/or its agent shall provide Buyer thirty (30) Days advance written notice of non-renewal, cancellation, substantial amendment or alteration of such coverage and ten (10) Days prior written notice to the Buyer by certified mail in the event of nonpayment of the premium. Upon request, the Seller shall provide to Buyer copies of the insurance certificates for Buyer’s internal purpose(s).

(c) Seller acknowledges Seller’s obligation to obtain and maintain appropriate insurance coverages for the benefit of Seller (and Seller’s employees, if any). If Seller fails to comply with the obligations for insurance required herein, Buyer shall have the right, but not the obligation, to purchase such insurance at Seller’s sole cost and expense and shall invoice, withhold payment or back charge Seller for the cost incurred by Buyer to satisfy such obligations. Seller waives any rights to recovery from Buyer for any injuries that Seller (and/or the Seller’s employees) may sustain under the Agreement and that are a result of the negligence of Seller or Seller’s employees. Likewise, Buyer waives any rights to recovery from Seller for any injuries that Buyer (and/or Buyer’s employees) may sustain while performing Buyer’s obligations under the Agreement and that are a result of the negligence of Buyer or Buyer’s employees.

(d) Seller shall comply with the statutory insurance requirements for all jurisdictions in which it operates.

 

23.3

Buyer/Owner Insurance

(a) At no expense to Seller, from and after Financial Closing, Owner shall cause a Builder’s All-Risk insurance policy (“BAR Policy”) to be maintained in a coverage amount sufficient to cover the construction, commissioning, and testing of the Facility at the Site. Seller shall receive a waiver of subrogation to the extent of Buyer’s and Owner’s release and indemnity obligations contained in the Agreement.

(b) From and after Financial Closing or such other date as the Parties may mutually agree upon in writing (whether earlier or later), subject to prevailing terms in the insurance marketplace, Owner shall obtain air and ocean cargo coverage for all materials and equipment (including the Liquefaction Train System) shipped to the Site (other than locally procured materials) and insuring the interest of Buyer, Owner, the Lenders, Seller and Subcontractors

 

A-62


written on a warehouse to final destination basis from customary standard ICC (A) clause “all risk” air and marine perils while in transit. Such policy shall be written on CIF +10% or equivalent basis or in such other amounts acceptable to Buyer, Owner, the Lenders, and shall be subject to a per conveyance limit equivalent to the maximum value of the shipment. Such maximum value shall be determined before the inception of the policy. Seller shall be responsible for any required load survey costs incurred in connection with any shipment of the Liquefaction Train System, including but not limited to complying with Loss Control Warranty Wordings. Seller shall provide Buyer with schedules and notices of air, marine and land shipments, identifying (a) the equipment, (b) the equipment and values to be contained in each shipment, and (c) other specific information reasonably required by insurance underwriters (including the vessel and/or vehicle identification, the itinerary and schedule along with scheduled shipping dates from Seller’s, Subcontractor’s or their supplier’s warehouse), and thereafter monthly updates to Buyer and Buyer’s designated marine cargo insurer of any changes to the foregoing information. Seller shall not permit any significant shipment to be made until such notice is timely given. Shipping delays incurred by Seller or any Subcontractor as the result of delays in securing cargo insurance due to Seller’s failure to supply such notice on a timely basis shall not be the basis for a change order and shall not result in Buyer having any liability to Seller or any Subcontractor for any costs and expenses incurred in connection with such delays. Seller shall ensure that all significant shipments of cargo by Seller or any Subcontractors comply with requirements related thereto of insurance providers.

 

24.

CHANGE ORDERS

 

24.1

Buyer Change Order

Buyer may, at any time, by written notice to Seller, request an addition to, or deletion from, or other changes in obligations of Seller under Appendix C (Scope of Supply & Project Schedule) and/or items and Deliverables that are to be provided by Seller hereunder, including alterations to the Liquefaction Train System schedule or scope. Seller shall review and reasonably consider such requested change and shall make a written response concerning such change to Buyer within ten (10) Days after receiving such request from Buyer to confirm if Seller will pursue cost and schedule analysis. Within twenty (20) Days of the requested change Seller, will provide a written response to include Seller’s estimated lump-sum fixed cost associated with such requested change together with the estimated number of hours, average hourly rates and material quantities required to carry out such change. If the Parties agree upon such change, the Parties shall set forth the agreed-upon change in a written change order signed by all Parties in the form of Appendix I (a “Change Order”). Each Change Order shall constitute a final accord, satisfaction and settlement of all matters covered therein.

 

24.2

Seller Change Order

To the extent that (a) Seller experiences a Force Majeure Event or (b) a suspension is requested by Buyer in accordance with Clause 29.3, or (c) other circumstances occur which specifically entitle Seller to request a Change Order under the Agreement, if Seller desires to request an equitable adjustment to the Project Schedule and/or Contract Price, Seller shall give Buyer notice within fifteen (15) Days after Seller knows of the occurrence of the

 

A-63


event or circumstances giving rise to such request. Within fifteen (15) Days after the delivery of such notice, Seller shall provide Buyer with a written notice setting forth the reasons why Seller believes the Project Schedule or Contract Price should be adjusted and the requested adjustment to the Project Schedule or Contract Price, such written response to include Seller’s estimated lump-sum fixed cost associated with such requested change together with the estimated number of hours and material quantities required to carry out such change. If Buyer does not agree with such requested adjustment, then Buyer shall notify Seller and such disagreement shall be resolved pursuant to the procedures set forth in Clause 20. If Buyer accepts any such requested adjustment to the Project Schedule or Contract Price, a Change Order shall be executed by the Parties and the Project Schedule or Contract Price shall be adjusted in accordance with the terms of such Change Order.

 

24.3

No Interruption of Performance

Except insofar as a Change Order was to specifically modify one or more provisions or conditions of the Agreement, all other provisions and conditions of the Agreement shall remain unaffected. No Change Order shall be deemed issued, or agreed upon, due to a course of dealing or course of the performance of any obligations hereunder, including the performance of any obligations pursuant to any other Change Order, individually or collectively. Seller shall not commence to perform, or perform, any obligations constituting a change from the obligations hereunder, and Buyer shall have no liability to Seller for any such obligations performed, unless Seller and Buyer have executed a Change Order. Seller shall not suspend, in whole or in part, performance of the Agreement during any dispute over any Change Order or a request for a Change Order unless directed to do so by Buyer, provided that Seller shall not be obligated to proceed with a disputed requested change or a disputed item under a Change Order, until such dispute is resolved, unless (a) such disputed requested change(s) or disputed item(s) (i) have an aggregate value of less than [***] or (ii) is required to address health and safety or environmental issues or (b) Seller elects, at its discretion, to proceed with such disputed requested change or disputed item while the dispute is still pending, provided, further, that, in each such case, Seller shall proceed, without waiving any rights with respect to such disputed requested change or disputed item.

 

25.

PERFORMANCE GUARANTEES, PERFORMANCE TESTS AND PERFORMANCE LIQUIDATED DAMAGES

 

25.1

Performance Guarantees

Seller guarantees to Buyer that the following Performance Guarantees shall be satisfied in accordance with Appendix F (Performance Tests):

 

  (a)

the LNG production capacity (measured in MTPA) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be equal to or greater than the Liquefaction Train Production Capacity Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train;

 

A-64


  (b)

the LNG production capacity (measured in lbs/hr) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be equal to or greater than the Liquefaction Train System Production Capacity Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date;

 

  (c)

(i) the minimum performance guarantee with respect to power demand (measured in kWh/Tonne) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train Power Demand Minimum Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train; and

(ii) the full performance guarantee with respect to power demand (measured in kWh/Tonne) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train Power Demand Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train;

 

  (d)

(i) the minimum performance guarantee with respect to power demand (measured in kWh/Tonne) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train System Power Demand Minimum Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date; and

(ii) the full performance guarantee with respect to power demand (measured in kWh/Tonne) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train System Power Demand Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date;

 

  (e)

the full performance guarantee with respect to any loss in Mixed Refrigerant (measured in standard liters/minute) for the Liquefaction Train System, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Refrigerant Losses Performance Guarantee prior to shipment from the manufacturing facility;

 

  (f)

the quality of the LNG produced by the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall satisfy the LNG Quality Performance Guarantee, on or before the Guaranteed Liquefaction Train System Substantial Completion Date; and

 

A-65


  (g)

The Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, will run at the required capacity to meet Facility demand over a [***] hour continuous test period with [***] equivalent availability factor that accounts for any capacity de-ratings during the test period (the “Reliability Guarantee”). Seller shall have a maximum of [***] test periods allotted to satisfy the Reliability Guarantee before a change of equipment or software is required. The Performance Test for the Reliability Guarantee will be run concurrently with tests in Clause 25.1(b).

 

25.2

Performance Tests

Seller shall conduct in accordance with Appendix F (Performance Tests) (a) the Liquefaction Train Performance Tests for an individual Liquefaction Train only after such Liquefaction Train has achieved Ready for Test and (b) the Liquefaction Train System Performance Tests only after the Liquefaction Train System has achieved Ready for Test. Seller shall conduct the Performance Tests for each of the Liquefaction Trains, individually, and the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, under the conditions and in strict accordance with the requirements set forth in Appendix F (Performance Tests). If (A) the Liquefaction Train Performance Tests of an individual Liquefaction Train demonstrate that the Liquefaction Train Performance Guarantees for such Liquefaction Train System have been achieved or (B) the Liquefaction Train System Performance Tests demonstrate that the Liquefaction Train System Performance Guarantees have been achieved, then Seller shall provide Buyer with written notice of such occurrence and shall provide Buyer with a test report, together with supporting documentation, demonstrating the achievement of the applicable Performance Guarantees within ten (10) Days of the date of the completion of such Performance Tests and upon receipt of such documentation Buyer shall, within ten (10) Days, either (A) confirm in writing to Seller the successful completion of the Liquefaction Train Performance Tests or the Liquefaction Train System Performance Tests or (B) provide written notice to Seller of why Buyer disagrees that the Liquefaction Train Performance Guarantees or the Liquefaction Train System Performance Guarantees have been achieved. If any Performance Test indicates that an individual Liquefaction Train or the Liquefaction Train System fails to achieve any Performance Guarantee for reasons attributable to Seller, its Affiliates or Subcontractors, then Seller shall, at its own cost and expense, take appropriate corrective action and Seller shall thereafter reperform the Performance Test.

Seller’s obligation to meet the Liquefaction Train Performance Guarantees under this Clause 25 shall be satisfied when (i) all the Liquefaction Train Performance Tests have been completed, and (ii) either (1) such tests demonstrate that all Liquefaction Train Performance Guarantees are met or (2) such tests demonstrate that the Liquefaction Train Power Demand Minimum Performance Guarantee is met and Seller has paid all payable liquidated damages for the Liquefaction Train Performance Guarantees that are not met.

 

A-66


Seller’s obligation to meet the Liquefaction Train System Performance Guarantees under this Clause 25 shall be satisfied when (i) all the Liquefaction Train System Performance Tests have been completed, and (ii) either (1) such tests demonstrate that all Liquefaction Train System Performance Guarantees are met or (2) such tests demonstrate that the Liquefaction Train Power Demand Minimum Performance Guarantee and the Refrigerant Losses Performance Guarantee are met and Seller has paid all payable liquidated damages for the Liquefaction Train System Performance Guarantees that are not met.

At all times during start-up, testing and commissioning of the Liquefaction Train System, Owner may, at no expense to Seller, arrange for the disposition of the Facility’s LNG. Owner shall have all right, title and interest to all LNG produced by the Facility and all of the proceeds from the sale thereof.

 

25.3

Performance Liquidated Damages and Performance Delay Liquidated Damages

(a) Performance Liquidated Damages

 

  (i)

If Seller achieves the Liquefaction Train Power Demand Minimum Performance Guarantee but fails to achieve the Liquefaction Train Power Demand Performance Guarantee for a Liquefaction Train, then Seller shall pay to Buyer [***] Dollars [***] for each kWh/Tonne of LNG produced above the Liquefaction Train Power Demand Performance Guarantee (the “Liquefaction Train Power Demand Liquidated Damages”).

 

  (ii)

If Seller achieves the Liquefaction Train System Power Demand Minimum Performance Guarantee but fails to achieve the Liquefaction Train System Power Demand Performance Guarantee, then Seller shall pay to Buyer [***] Dollars [***] for each kWh/Tonne of LNG produced above the Liquefaction Train System Power Demand Performance Guarantee (the “Liquefaction Train System Power Demand Liquidated Damages”).

 

  (iii)

The total amount of Performance Liquidated Damages payable by Seller to Buyer shall not exceed the Performance Liquidated Damages Cap and the total amount of Liquidated Damages payable by Seller to Buyer shall not exceed the Liquidated Damages Cap. Once Seller has accrued (i) Performance Liquidated Damages in amount equal to the Performance Liquidated Damages Cap or (ii) Liquidated Damages in amount equal to the Liquidated Damages Cap, [***].

 

  (iv)

The assessment of Liquefaction Train Power Demand Liquidated Damages will not apply concurrently with Liquefaction Train System Power Demand Liquidated Damages.

 

A-67


(b) Performance Delay Liquidated Damages

 

  (i)

If Seller fails to achieve the Liquefaction Train Production Capacity Performance Guarantee for a Liquefaction Train on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train, then Seller shall pay to Buyer an amount equal to: (x) in respect of the first [***] Liquefaction Trains to be performance tested, (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each Day of such delay for the next [***]; and (y) in respect of the subsequent [***] Liquefaction Trains to be performance tested, (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] Dollars ([***]) per Day for each Day of such delay for the next [***] (the “Liquefaction Train Production Capacity Liquidated Damages”).

 

  (ii)

If Seller fails to achieve either the Liquefaction Train System Production Capacity Performance Guarantee, or the LNG Quality Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date, then Seller shall pay to Buyer an amount equal to (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] Dollars ([***]) per Day for each Day of such delay for the next [***] (the “Liquefaction Train System Production Capacity Liquidated Damages” or the “LNG Quality Liquidated Damages”, as applicable).

 

  (iii)

The aggregate amount of Performance Delay Liquidated Damages payable by Seller to Buyer for each Liquefaction Train shall not exceed the applicable Performance Delay Liquidated Damages Cap. The aggregate amount of Liquefaction Train System Production Capacity Liquidated Damages and LNG Quality Liquidated Damages payable shall not exceed, in the aggregate, the Liquefaction Train System Performance Delay Liquidated Damages Cap. Once Seller has accrued (i) Performance Delay Liquidated Damages in amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (ii) Liquidated Damages in amount equal to the Liquidated Damages Cap, [***].

 

  (c)

Buyer shall invoice Seller on a monthly basis for any amounts due for Performance Liquidated Damages and Performance Delay Liquidated Damages. Payment of any Performance Liquidated Damages and Performance Delay Liquidated Damages by Seller shall occur within ten (10) Business Days following the date Buyer submits to Seller an invoice therefore. Buyer and Seller agree that the amount of Performance Liquidated Damages and Performance Delay Liquidated Damages are

 

A-68


reasonable in light of the anticipated harm caused by the breach of duty related thereto and the difficulties of proof of loss and inconvenience or non-feasibility of obtaining any adequate remedy with respect to the actual level of damages Buyer is likely to suffer in the event that Seller fails to achieve the (i) Liquefaction Train Power Demand Performance Guarantee, (ii) Liquefaction Train System Power Demand Performance Guarantee, or (iii)(A) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (B) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, and the Parties are estopped from contesting the validity or enforceability of such liquidated damages. Except as provided in Clause 28.1 and Clause 28.3, the payment of Performance Delay Liquidated Damages shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for Seller’s failure to achieve (w) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (x) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date. Except as provided in Clause 28.1 and Clause 28.3, the payment of Performance Liquidated Damages shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for Seller’s failure to achieve (y) the Liquefaction Train Power Demand Performance Guarantee or (z) the Liquefaction Train System Power Demand Performance Guarantee. In the event the Performance Liquidated Damages or Performance Delay Liquidated Damages provisions are found for any reason to be void, invalid or otherwise inoperative so as to disentitle Buyer from claiming and recovering Performance Liquidated Damages or Performance Delay Liquidated Damages from Seller, Buyer shall, in addition to the remedies set forth below in Clause 25.4, be entitled to claim against Seller and recover for damages for Seller’s failure to achieve (1) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train, (2) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, (3) Liquefaction Train Power Demand Performance Guarantee or (4) Liquefaction Train System Power Demand Performance Guarantee; provided that such damages shall not exceed, in the case of Clauses (1) and (2), the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, and, in the case of Clauses (3) and (4), the Performance Liquidated Damages Cap.

 

25.4

Buyer Remedies

If Seller has accrued an aggregate amount of (i) Performance Liquidated Damages in an amount equal to the Performance Liquidated Damages Cap, (ii) Performance Delay Liquidated Damages in an amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (iii) Liquidated Damages in an amount equal to the Liquidated Damages Cap, then Buyer may by notice to Seller, at Buyer’s sole discretion, either:

 

  (a)

[***]

 

  (b)

[***]

 

A-69


25.5

Performance Guarantees [***]

Seller acknowledges and agrees that its Unconditional Performance Obligation is [***].

 

26.

ACCESS AFTER DELIVERY

For the sole purpose of (and to the extent necessary for) performing its obligations under the Agreement regarding the remedying of Defects or guaranteed performance, Seller may request Buyer (who shall not unreasonably withhold its consent) to have the right of access to all parts of the Liquefaction Train System(s). Such access shall only be granted during normal working hours and will be limited to the duly authorized representatives of Seller, provided that (a) Seller shall, and shall cause its authorized agents, employees and inspectors to, at all times comply with Buyer’s safety and security requirements when present at the Site and (b) Seller shall not, and shall cause its authorized agents, employees and inspectors not to, interfere with the operation of any Liquefaction Train System or the Facility. Seller understands and acknowledges that the Liquefaction Trains will commence commercial operations prior to the Substantial Completion of the Facility.

 

A-70


27.

QUALITY ASSURANCE AND QUALITY CONTROL

The quality control exercised by Seller in its manufacture of the Liquefaction Train System shall be in accordance with the standards set forth in Appendix E (Quality Assurance and Quality Control).

 

28.

EVENTS OF DEFAULT; REMEDIES

 

28.1

Events of Default for Seller

Each of the following events constitutes an Event of Default of Seller under the Agreement:

 

  (a)

Seller fails to make when due any payment (other than amounts disputed in good faith) due and owing under the Agreement and such failure is not cured within ten (10) Working Days after Buyer notifies Seller of such failure;

 

  (b)

Seller is in material breach of its obligations under the Agreement (other than an obligation to make payment or an obligation that is otherwise specifically set forth in this Clause 28.1 as a separate Event of Default) and such material breach is not remedied within thirty (30) Days after Buyer notifies Seller of such material breach, which notice sets forth in reasonable detail the nature of such material breach, provided that if such material breach is not reasonably capable of being remedied within the thirty (30) Day remedy period specified above but is reasonably capable of being remedied, Seller shall have an additional sixty (60) Day remedy period to remedy such material breach, so long as Seller promptly commences and thereafter diligently pursues such remedy;

 

  (c)

Seller fails to establish or maintain the credit support required under Clause 7.9, and such breach is not cured within ten (10) Working Days after written notice of such breach from Buyer;

 

  (d)

Any representation or warranty made by Seller in Clause 32.2 is not true in all material respects as of the date made and such inaccuracy is not cured within thirty (30) Days after Buyer notifies Seller of such inaccuracy, which notice sets forth in reasonable detail the nature of the inaccuracy;

 

  (e)

A Bankruptcy Event occurs with respect to Seller;

 

  (f)

Seller assigns the Agreement, except as described in Clause 4.1;

 

  (g)

If Seller has accrued an aggregate amount of Delivery Delay Liquidated Damages in an amount equal to the Delivery Delay Liquidated Damages Cap or Aggregate Delivery Delay Liquidated Damages Cap, as applicable, and has not delivered all of the Liquefaction Trains (in their entirety) to the Delivery Point; and

 

A-71


  (h)

If Seller has accrued an aggregate amount of (i) Performance Liquidated Damages in an amount equal to the Performance Liquidated Damages Cap, (ii) Performance Delay Liquidated Damages in an amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (iii) Liquidated Damages in an amount equal to the Liquidated Damages Cap and Seller has failed to achieve (A) the Liquefaction Train Performance Guarantees for any Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (B) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, (C) Liquefaction Train Power Demand Performance Guarantee or (D) Liquefaction Train System Power Demand Performance Guarantee.

If an Event of Default with respect to Seller has occurred, Buyer will have the right, but not the obligation, at any time when such Event of Default is continuing, to designate by notice to Seller a date for terminating the Agreement that will be no earlier than thirty (30) Days after the notice is deemed delivered. Upon the date designated as the termination date by Buyer as a result of an Event of Default of Seller, Buyer shall suspend any further payment to Seller under the Agreement.

 

28.2

Events of Default for Buyer

Each of the following events constitutes an Event of Default of Buyer under the Agreement:

 

  (a)

Buyer fails to make when due any payment (other than amounts disputed in good faith) due and owing under the Agreement and such failure is not cured within ten (10) Working Days after Seller notifies Buyer of such failure;

 

  (b)

Buyer is in material breach of its obligations under the Agreement (other than an obligation to make payment or an obligation that is otherwise specifically set forth in this Clause 28.2 as a separate Event of Default) and such material breach is not remedied within thirty (30) Days after Seller notifies Buyer of such material breach, or if such material breach cannot be reasonably remedied within such thirty (30) Day period, Buyer has not commenced to cure such material breach within thirty (30) Days of notice from Seller, which notice sets forth in reasonable detail the nature of such material breach, provided that if such material breach is not reasonably capable of being remedied within the thirty (30) Day remedy period specified above but is reasonably capable of being remedied, Buyer shall have an additional sixty (60) Day remedy period to remedy such material breach, so long as Buyer promptly commences and thereafter diligently pursues such remedy;

 

A-72


  (c)

Buyer fails to establish or maintain the credit support as required by Clause 7.8 and such breach is not cured within ten (10) Working Days after written notice of such breach from Seller;

 

  (d)

Any representation or warranty made by Buyer in Clause 32.1 is not true in all material respects as of the date made and such inaccuracy is not cured within thirty (30) Days after Seller notifies Buyer of such inaccuracy, which notice sets forth in reasonable detail the nature of the inaccuracy;

 

  (e)

A Bankruptcy Event occurs with respect to Buyer; and

 

  (f)

Buyer assigns the Agreement, except as described in Clause 4.1.

If an Event of Default with respect to Buyer has occurred, Seller will have the right, but not the obligation, at any time when such Event of Default is continuing, to designate by notice to Buyer a date for terminating the Agreement that will be no earlier than thirty (30) Days after the notice is deemed delivered. Upon the date designated as the termination date by Seller as a result of an Event of Default of Buyer, Seller shall (i) terminate performance of its obligations under the Agreement; and (ii) invoice Buyer in connection with any obligations performed under the Agreement for which Seller has not received payment by Buyer.

 

28.3

Remedies

Upon any termination of the Agreement (including by Buyer under Clause 6.5(b) or Clause 29.1), Seller shall deliver to Buyer the portions of the Liquefaction Train System for which Seller has received payment and which have not been delivered to the Delivery Point. Except where exclusive and/or sole remedies are expressly provided herein, (a) remedies available to each Party under the Agreement are cumulative and (b) whether or not the Agreement is terminated in accordance with this Clause 28, each Party may assert any claims under the Agreement, at law or in equity against the other Party for damages incurred by such Party resulting from any breach of, or default under, the Agreement by the other Party; but the Parties agree that such remedies and claims for damages incurred by such Party resulting from any breach of, or default under, the Agreement by the other Party are always subject to the (i) limitations and exclusions of liability and (ii) dispute resolution provisions provided for in the Agreement; provided, further, that the Delivery Delay Liquidated Damages Cap, Aggregate Delivery Delay Liquidated Damages Cap, the Aggregate Performance Delay Liquidated Damages Cap, the Performance Delay Liquidated Damages Cap, the Liquefaction Train System Performance Delay Liquidated Damages Cap, the Performance Liquidated Damages Cap and the Liquidated Damages Cap shall not be construed to limit either Party’s liability hereunder upon a termination of the Agreement. Each Party agrees that it has a duty to mitigate Costs and covenants that it will use commercially reasonable efforts to minimize any Costs, including termination Costs that it may incur as a result of the other Party’s performance or non-performance hereof. Neither the termination nor expiration of the Agreement will relieve either Party of: (i) any undischarged liability of such Party in respect of the period prior to such termination or expiration (including for unpaid amounts owing under the Agreement in respect of the period prior to such termination or expiration, including payments due as a result of events occurring prior to such termination or expiration); or (ii) any liability for breach by such Party of the Agreement.

 

A-73


29.

TERMINATION AND SUSPENSION

 

29.1

Termination by Buyer

Buyer may at any time terminate the Agreement for its convenience by giving Seller [***] written notice of termination, but subject to payment of the Termination Fees in accordance with Clause 29.2. The Agreement shall terminate with effect from the date indicated in such notice.

 

29.2

Termination Fee

In the event of a termination of the Agreement by Buyer under Clause 29.1, Buyer shall pay to Seller the applicable termination payment, as determined in accordance with Appendix B (Pricing; Payment Terms & Cancellation Schedule) (the “Termination Fee”), provided that under no circumstances shall the Termination Fee exceed the applicable maximum Termination Fee set forth in the table in Appendix B (Pricing; Payment Terms & Cancellation Schedule) (the “Maximum Termination Fee”). The Termination Fee, if any, shall be paid within thirty (30) Days from Seller’s invoice therefor. The Termination Fee, if any, shall be Seller’s sole and exclusive remedy and Buyer’s sole and exclusive liability for a termination of the Agreement by Buyer for Buyer’s convenience. BUYER AND SELLER AGREE THAT THE TERMINATION FEE REPRESENTS AN ACCURATE, REASONABLE AND CONSERVATIVE ESTIMATE OF THE ACTUAL LEVEL OF DAMAGES SELLER IS LIKELY TO SUFFER IN THE EVENT OF SUCH TERMINATION.

 

29.3

Order to Suspend Execution of the Agreement

 

  (a)

Buyer may at any time, upon thirty (30) Days’ prior written notice, instruct Seller to suspend the performance of Seller’s obligations under the Agreement or any portion thereof for such time and in such manner as Buyer may reasonably consider necessary. Upon receiving any such notice of suspension, Seller shall: (i) properly protect and secure the Liquefaction Train System against any deterioration, loss or damage, as considered necessary or required by Buyer; (ii) place no further purchase orders or subcontracts for materials, services or facilities with respect to the suspended performance; (iii) promptly make every reasonable effort to obtain suspension, with terms satisfactory to Buyer of all subcontracts with all Subcontractors to the extent they related to the suspended performance; and (iv) take any other reasonable steps to minimize costs and expenses associated with such suspension.

 

A-74


  (b)

Any Costs reasonably incurred and properly documented by Seller (including, but not limited to, demobilization and/or remobilization, storage, preservation, inspection, related labor and any other costs due to such suspension) in giving effect to Buyer’s suspension instructions under this Clause 29.3, shall be borne and paid by Buyer, or, unless such suspension is (i) necessary by reason of a breach or Event of Default on the part of Seller or (ii) due to a Force Majeure Event.

 

  (c)

If Buyer is in breach of its obligation to timely pay undisputed amounts owed to Seller under the Agreement, Seller may suspend immediately upon written notice to Buyer, without penalty and without further proof or establishment of cause, the performance of Seller’s obligations until such undisputed payment is made by Buyer. Seller shall be entitled to request a Change Order for an equitable adjustment of the Project Schedule to the extent that such Seller suspension adversely affects the delivery of any Liquefaction Train in accordance with the Project Schedule. Any Costs reasonably incurred and properly documented by Seller in accordance with such suspension (including storage, demobilization and re-mobilization costs) shall be payable by Buyer within thirty (30) Days of receipt of Seller’s invoices, provided Seller shall exercise commercially reasonable efforts to mitigate and minimize such Costs.

 

29.4

Resumption of Works

At any time after a suspension under Clause 29.3, Buyer may give written notice to Seller to proceed with the delivery of the Liquefaction Trains and/or with the execution of all or part of the Agreement suspended under this Clause 29. Seller will be entitled to a Change Order to equitably adjust the Contract Price and the Project Schedule prior to resuming performance.

 

29.5

Prolonged Suspension

If the performance of Seller’s obligations under the Agreement or any portion thereof is suspended pursuant to Clause 29.3 for more than [***] in the aggregate during the term of the Agreement, then Seller may serve notice in writing to Buyer requesting permission to proceed with the Agreement or the portion in regard to which progress is suspended. If such permission to proceed is not granted by Buyer within [***] of Buyer’s receipt of such notice, either Party may, by a further prior written notice to the other Party, elect to terminate the Agreement. Seller shall transfer or assign to Buyer, title in the part of the Liquefaction Train System for which payment has been received in full as of the date of any termination of the Agreement. This Clause 29.5 shall not apply if the suspension was (i) necessary by reason of some material default on the part of Seller or (ii) due to a Force Majeure Event.

 

A-75


30.

GENERAL CLAUSES

 

30.1

No Third Party Beneficiary

The Parties expressly agree that Owner shall be a third party beneficiary of the Agreement entitled, in its own name, in the name of Buyer or in the name of any assignee of Buyer to enforce the Agreement against Seller (subject to such enforcement being subject to all the limitations, exclusions, remedies and defenses provided to Seller under the Agreement). Except as provided in the foregoing sentence with respect to Owner and in Clause 18.8, Clause 19.2 and Clause 19.3 with respect to the Buyer Parties and the Seller Parties, the provisions of the Agreement are for the benefit of the Parties hereto and not for any other third party. The Agreement shall be binding upon and inure to the benefit of each of the Parties and their respective successors and permitted assigns.

 

30.2

Severability

Should a determination be made by a court of competent jurisdiction that any provision of the Agreement is illegal, invalid or otherwise unenforceable, the same shall not affect the other terms or provisions of the Agreement, but such provisions shall be deemed modified to the extent necessary in the court’s opinion to render such term or provision enforceable, and the rights and obligations of the Parties shall be construed and enforced accordingly, preserving to the fullest extent possible the intent and agreements of the Parties set forth herein.

 

30.3

Counterparts

The Agreement may be executed in one or more counterparts, each of which shall be deemed an original, but all of which taken together shall constitute one and the same instrument. Signatures may be delivered electronically or by facsimile, and such copies shall be treated as originals for all purposes.

 

30.4

Attorney Review

The Parties acknowledge that each Party and its attorney have reviewed the Agreement and that any rule of construction to the effect that any ambiguities are to be resolved against the drafting Party, or any similar rule operating against the drafter of an agreement, shall not be applicable to the construction or interpretation of the Agreement.

 

30.5

Time is of the Essence

Time is of the essence in the performance of the Agreement.

 

30.6

No Waiver

The waiver by a Party of a breach of any provision of the Agreement by the other Party shall not be construed as a waiver of any succeeding breach of the same or any other provision, nor shall any delay or omission on the part of a Party to exercise or avail itself of any right, power or privilege that it has, or may have, hereunder operate as a waiver of any right, power or privilege by such Party. Any consent or permission granted under the Agreement shall be effective only in the specific instance and for the specific purpose given.

 

A-76


30.7

Survival

Upon termination of the Agreement, the rights and obligations of the Parties hereunder shall terminate, except for: (i) provisions that are indicated herein as surviving and those provisions that by their nature are intended to survive; and (ii) rights and obligations accrued as of the date of termination and in connection therewith.

 

30.8

Relationship to Second Phase

The Parties acknowledge and agree that the Second LTS Purchase Order is an independent agreement between the Parties and, notwithstanding anything contained herein to the contrary, the Agreement shall not be construed to interpret or modify, or otherwise challenge the enforceability of or invalidate, the Second LTS Purchase Order.

 

31.

HAZARDOUS MATERIALS

 

31.1

Hazardous Materials

Seller shall, and shall cause all of its Subcontractors to, comply with all applicable Laws relating to Hazardous Materials. If Seller is performing any of its obligations hereunder at the Site, Seller shall not, nor shall it permit any Subcontractor to, bring, introduce, use or release any Hazardous Material on or at the Site. Seller shall be responsible for the management, storage, disposal, removal, treatment and/or remediation of any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site. In addition, Seller shall not, and shall cause its Subcontractors to not, take any action or fail to take any action, that may disrupt, release or exacerbate, or render more costly the removal or remediation of, any Hazardous Materials existing on the Site prior to the date Seller commences the performance of its obligations hereunder on the Site. Seller shall indemnify, defend, release and hold harmless the Buyer Parties from any costs, expenses or liability resulting from any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site, to the extent resulting from Seller’s or its Subcontractors’ fault, negligence (in any form) or willful misconduct. Buyer shall indemnify, defend, release and hold harmless the Seller Parties from any costs, expenses or liability resulting from any Hazardous Material use or releases on or at the Site, excluding any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site.

 

31.2

Notification

If Seller encounters a condition at the Site involving a Hazardous Material or if Seller or anyone for whom Seller is responsible creates a condition involving a Hazardous Material, Seller shall promptly: (a) secure or otherwise isolate such condition, (b) stop its performance of its obligation hereunder in connection with such condition and in any area affected thereby and not take any action that may disrupt, release or exacerbate any such condition, and (c) verbally notify Buyer (and promptly thereafter confirm such notice of such condition in writing). Seller shall cooperate with and assist Buyer in making the Site available for the taking of necessary remedial steps.

 

A-77


32.

REPRESENTATIONS AND WARRANTIES

 

32.1

Buyer Representations and Warranties

Buyer hereby represents and warrants to Seller that as of the Effective Date: (a) Buyer is a limited liability company duly organized, validly existing and in good standing under the laws of its state of organization and has all requisite limited liability company power and authority to own and operate its properties and assets and to carry on its business as now conducted; (b) Buyer is duly qualified and is authorized to transact business and is in good standing as a foreign organization in each jurisdiction in which the failure so to qualify would have a material adverse effect on its ability to perform its obligations under the Agreement; (c) all limited liability company action on its part and on the part of its officers, managers and/or members necessary for the authorization, execution and delivery of the Agreement and the performance by it of all of its obligations hereunder have been taken; (d) it has obtained all governmental approvals or third party approvals required for the performance by it of its obligations under the Agreement; (e) there is no action pending or, to its knowledge, currently threatened against it that seeks to prohibit the transactions contemplated by the Agreement or adversely affect its ability to perform under the Agreement; and (f) the Agreement constitutes the legal, valid and binding obligation of Buyer, enforceable in accordance with its terms (subject to principles of equity, the effect of bankruptcy, insolvency, reorganization, receivership, moratorium, and other similar laws), and the execution, delivery and performance of the Agreement by Buyer does not and will not, in any material respect, conflict with, violate or cause a breach of any applicable Law, material agreement, contract or instrument to which Buyer is a party or any judgment, order or decree to which Buyer is subject.

 

32.2

Seller Representations and Warranties

Seller hereby represents and warrants to Buyer that as of the Effective Date: (a) Seller is a limited liability company duly organized, validly existing and in good standing under the laws of its state of organization and has all requisite limited liability company power and authority to own and operate its properties and assets and to carry on its business as now conducted; (b) Seller is duly qualified and is authorized to transact business and is in good standing as a foreign organization in each jurisdiction in which the failure so to qualify would have a material adverse effect on its ability to perform its obligations under the Agreement; (c) all limited liability company action on its part and on the part of its officers, managers and/or members necessary for the authorization, execution and delivery of the Agreement and the performance by it of all of its obligations hereunder have been taken; (d) it has obtained all governmental approvals or third party approvals required for the performance by it of its obligations under the Agreement; (e) there is no action pending or, to its knowledge, currently threatened against it that seeks to prohibit the transactions

 

A-78


contemplated by the Agreement or adversely affect its ability to perform under the Agreement; (f) the Agreement constitutes the legal, valid and binding obligation of Seller, enforceable in accordance with its terms (subject to principles of equity, the effect of bankruptcy, insolvency, reorganization, receivership, moratorium, and other similar laws), and the execution, delivery and performance of the Agreement by Seller does not and will not, in any material respect, conflict with, violate or cause a breach of any applicable Law, material agreement, contract or instrument to which Seller is a party or any judgment, order or decree to which Seller is subject.

 

33.

FORCE MAJEURE

 

33.1

Force Majeure Event

 

  (a)

Each Party shall not be liable or be considered to be in breach or default of its obligations under the Agreement to the extent that performance of such obligations is delayed or prevented, by a Force Majeure Event. A “Force Majeure Event” means any cause or event, or any combination of any causes or events, that: (i) is unforeseeable; (ii) is beyond the reasonable control and without fault or negligence of the affected Party; (iii) could not have been prevented in whole or in part by the exercise of reasonable care and skill by the affected Party; and (iv) materially impairs or prevents the performance of obligations under the Agreement by the affected Party. Subject to the requirements of the preceding sentence, Force Majeure Events may include, but are not limited to, acts of God or the public enemy, acts (or omissions) of Governmental Authorities, fires, severe weather conditions, earthquakes, strikes or other labor disturbances, floods, war (declared or undeclared), armed conflict, acts or threats of terrorism, epidemics (including the pandemic known as COVID-19), civil unrest, riot, delays or interruptions of or by any Governmental Authority of the Country or of any other governments having jurisdiction, embargoes or quarantines. The Parties acknowledge that the Agreement reflects the impact of the COVID-19 epidemic as of the Effective Date. To the extent new adverse circumstances pertaining to the COVID-19 epidemic arise after the Effective Date, each Party shall continue to work in good faith to mitigate any resulting impact, and shall be entitled, if and to the extent applicable, to relief in accordance with this Clause 33.

 

  (b)

For the avoidance of doubt, a Force Majeure Event does not include (except and to the extent that they result directly from a Force Majeure Event), among others: (i) technical failures, normal wear and tear in machinery, or breakdown in equipment; (ii) shortage of parts, materials or other similar circumstances for which Seller may be responsible pursuant to the Agreement; (iii) late or non-delivery of machinery, equipment, materials or spare parts; (iv) a delay or default in the performance of any Subcontractor or supplier, or any other contractor; (v) strike or labor disturbances limited in scope to those solely affecting Seller or any of its Major Subcontractors; and (vi) changes since the date hereof in applicable Laws or their interpretation.

 

A-79


33.2

Force Majeure Relief

So long as the affected Party has at all times since the occurrence of the Force Majeure Event complied with the obligations of this Clause 33 and continues to so comply, then:

 

  (a)

the affected Party shall not be liable for any failure or delay in performing its obligations which are affected by the Force Majeure Event under or pursuant to the Agreement during the existence of a Force Majeure Event;

 

  (b)

each Party will bear its Cost caused by the circumstances of the Force Majeure Event; and

 

  (c)

in case of a Force Majeure Event affecting Seller, Buyer shall be released from its payment obligations under the Agreement, other than in respect of any amounts that became due and owing under the Agreement prior to the occurrence of the Force Majeure Event that are unpaid, for the duration of the Force Majeure Event.

If Seller claims a Force Majeure Event, Seller shall be entitled to request a Change Order pursuant to Clause 24, in order to obtain an equitable suspension of performance or extension of time (including an extension of the Project Schedule to the extent compliance thereof is affected) with respect thereto.

 

33.3

Notice of Force Majeure

If either Party considers that a Force Majeure Event has occurred which may affect performance of its obligations, it shall notify the other Party as soon as possible but within a maximum of ten (10) Days from the Force Majeure Event occurrence date (or from the date it became aware of the occurrence) giving written particulars of the relevant event and its effect upon its performance under the Agreement and, where known, the expected duration of the failure to perform. If the Party declaring a Force Majeure Event does not notify the other Party within such ten (10) Day period, then any relief provided to the declaring Party under this Clause 33 shall only be available as of the date that such notice was provided to the other Party. As soon as the Force Majeure Event has ended, the Party claiming such Force Majeure Event shall give written notice to the other Party of the precise date of the end of the Force Majeure Event and the extent, with justification, to which it has actually been affected in the performance of its obligations.

 

33.4

Force Majeure Report

Upon the occurrence of any Force Majeure Event, Seller shall use its best efforts to continue to perform its obligations under the Agreement and to minimize the adverse effects of such Force Majeure Event. Seller shall notify Buyer of the steps it proposes to take including any reasonable alternative means to continue the performance of its obligations under the Agreement. Seller shall not take any such steps unless approved by Buyer. In the case of Seller declaring a Force Majeure Event, within twelve (12) Days after giving such notice Seller shall prepare and deliver to Buyer an appraisal report of the effects of the Force Majeure Event (the “Force Majeure Report”). The Force Majeure Report shall:

 

  (a)

specify the Force Majeure Event;

 

A-80


  (b)

describe the damage to and/or other effects on the Liquefaction Train System resulting from the Force Majeure Event; and,

 

  (c)

provide a good faith estimate (in each case to the extent applicable in the circumstances) of:

 

  (i)

the time it will take to restore such condition;

 

  (ii)

the effect which the relevant Force Majeure Event is likely to have upon any other contract relating to the Agreement;

 

  (iii)

whether or not, in Seller’s opinion, the completion or continued manufacturing of the Liquefaction Train System is technically viable with the reasons for such opinion; and

 

  (iv)

include all relevant supporting documentation.

In addition to the Force Majeure Report, Buyer may request, and Seller shall promptly provide, such related information pertaining to the Force Majeure Report as may be reasonable.

 

33.5

Termination for Force Majeure

If circumstances or consequences of a Force Majeure Event have occurred and shall continue for an uninterrupted period of [***] after date of occurrence then, notwithstanding that Seller may by reason thereof have been granted an extension of the Delivery Date, the non-claiming Party shall be entitled to serve upon the Party affected by the Force Majeure Event an additional fifteen (15) Days’ notice to terminate the Agreement. If, at the expiry of such period, the Force Majeure Event is still in effect, the Agreement shall terminate. In the event of a termination of the Agreement due to a Force Majeure Event, the following provisions shall apply:

 

  (a)

neither Party shall have any liability to the other in respect of termination of the Agreement due to a Force Majeure Event, but rights and liabilities which have accrued prior to termination shall survive;

 

  (b)

upon such termination, Seller shall transfer or assign to Buyer, title in the part of the Liquefaction Train System for which payment has been received in full as of the date of the termination of the Agreement under this Clause 33.5; and

 

  (c)

upon such termination, Buyer shall pay to Seller any unpaid amounts due Seller for Payment Milestones completed as of the date of termination.

 

A-81


34.

LIMITED RECOURSE

 

  (a)

Except to the extent as otherwise provided in any parent guarantee provided to Seller under the Agreement, in the event of non-performance by Buyer of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (i) any assets or properties of any of the shareholders, members or partners of the Buyer, (ii) any Affiliate of Buyer or (iii) any officers, directors or employees thereof, and no judgment relating to the obligations of Buyer under the Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of Buyer or any other officer, employee or director past, present or future of Buyer or any of its shareholders, members, partners or Affiliates.

 

  (b)

Except to the extent otherwise provided in any parent guarantee provided to Buyer under the Agreement, in the event of non-performance by Seller of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (i) any assets or properties of any of the shareholders, members or partners of the Seller, (ii) any Affiliate of Seller or (iii) any officers, directors or employees thereof, and no judgment relating to the obligations of Seller under the Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of the Seller or any other officer, employee or director past, present or future of the Seller or any of its shareholders, members, partners or Affiliates.

 

A-82


APPENDIX B

PRICING; PAYMENT TERMS & CANCELLATION SCHEDULE

See attached.

 

B-1


APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one (1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement.

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders.

In addition to the amounts shown in the Payment Milestone in Section I.B., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] during the first [***] of the Payment Schedule following the issuance of FNTP and [***] during the [***] of the Payment Schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the transportation fixed fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of $[***]. In all other cases, Facility-specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Cameron Parish sales and use taxes that constitute Buyer Taxes. Any such Cameron Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.

 

B-2


I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of Pre-LNTP and/or LNTP shall be as indicated in the table below.

 

Type

  

Milestone

  

Payment Milestone Description

  

Amount

(USD)

[***]

   1    [***]    [***]

[***]

   L1    [***]    [***]

[***]

   2    [***]    [***]

[***]

   3    [***]    [***]

[***]

   4    [***]    [***]

[***]

   5    [***]    [***]

[***]

   6    [***]    [***]

 

B-3


  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.

 

Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   1    [***]    [***]

[***]

   L1    [***]    [***]

[***]

   2    [***]    [***]

[***]

   3    [***]    [***]

[***]

   4    [***]    [***]

[***]

   5    [***]    [***]

[***]

   6    [***]    [***]

[***]

   7    [***]    [***]

[***]

   8    [***]    [***]

[***]

   9    [***]    [***]

[***]

   10    [***]    [***]

[***]

   11    [***]    [***]

[***]

   12    [***]    [***]

 

B-4


Type

  

Milestone

  

Milestone Description

  

Amount

(USD)

[***]

   13    [***]    [***]

[***]

   14    [***]    [***]

[***]

   15    [***]    [***]

[***]

   16    [***]    [***]

[***]

   17    [***]    [***]

[***]

   18    [***]    [***]

[***]

   19    [***]    [***]

[***]

   20    [***]    [***]

[***]

   21    [***]    [***]

[***]

   22    [***]    [***]

[***]

   23    [***]    [***]

[***]

   24    [***]    [***]

[***]

   25    [***]    [***]

[***]

   26    [***]    [***]

[***]

   27    [***]    [***]

[***]

   28    [***]    [***]

[***]

   29    [***]    [***]

[***]

   30    [***]    [***]

 

B-5


Payment Milestone Note

1

   [***]

2

   [***]

3

   [***]

4

   [***]

5

   [***]

6

   [***]

7

   [***]

8

   [***]

9

   [***]

10

   [***]

11

   [***]

 

B-6


Payment Milestone Note

12

   [***]

 

B-7


Payment Milestone Note

13

   [***]

14

   [***]

 

B-8


II.

Aggregate Payment Milestone Cap:

The aggregate amount of all Payment Milestones invoiced by Seller as of each month, including all invoices submitted to Buyer in prior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month.

 

  A.

[***]

 

Month after Issuance

of Pre-LNTP or LNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

  B.

[***]

 

Month after Issuance of Pre-LNTP or

LNTP or FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-9


Month after Issuance of Pre-LNTP or

LNTP or FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-10


Month after Issuance of Pre-LNTP or

LNTP or FNTP, as applicable

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-11


III.

Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29.1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]

where:

[***]

 

Months after issuance of Pre-LNTP,

or LNTP or issuance of a Suspension

Notice, as Applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-12


Months after issuance of Pre-LNTP,

or LNTP or issuance of a Suspension

Notice, as Applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

 

4.

If LNTP is issued and FNTP is subsequently issued prior to the termination of the Agreement, the Maximum Termination Fee shall be as follows; provided, however, that if (a) no LNTP is issued but the FNTP is issued or (b) FNTP is issued less than [***] after the issuance of LNTP, in either case, the Maximum Termination Fee set forth in the first [***] in the table below shall be increased by [***].

 

Months after issuance of Pre-LNTP,

or LNTP or FNTP or issuance of a Suspension

Notice, as applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-13


Months after issuance of Pre-LNTP,

or LNTP or FNTP or issuance of a Suspension

Notice, as applicable

  

Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-14


APPENDIX C

SCOPE OF SUPPLY & PROJECT SCHEDULE

[Omitted]

 

C-1


APPENDIX D

GUARANTY AGREEMENT

[Omitted]

 

D-1


APPENDIX E

QUALITY ASSURANCE AND QUALITY CONTROL

[Omitted]

 

E-1


APPENDIX F

PERFORMANCE TESTS

[Omitted]

 

F-1


APPENDIX G

APPROVED SUBCONTRACTORS

[Omitted]

 

G-1


APPENDIX H

FORM OF SELLER PARENT COMPANY GUARANTEE

[Omitted]

 

H-1


APPENDIX I

FORM OF CHANGE ORDER

[Omitted]

 

I-1


APPENDIX J

FORM OF LIEN WAIVERS AND RELEASES

[Omitted]

 

J-1


APPENDIX K

PHYSICAL TRANSPORTATION COSTS

At least six (6) months prior to the delivery of the first Liquefaction Train under the Agreement, Seller shall provide to Buyer for Buyer’s review and approval, such approval not to be unreasonably withheld, conditioned or delayed, a plan for the delivery of the Liquefaction Trains in accordance with the delivery schedule, including the identity of the transportation vendors and the estimated Transportation Costs for the Agreement.

 

K-1


APPENDIX L

LIQUIDATED DAMAGE AMOUNTS

 

I.

Delivery Delay Liquidated Damages (Clause 6.4(c)(i)(1)):

 

Day

  

Liquidated Damage Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

II.

Delivery Delay Liquidated Damages (Clause 6.4(c)(ii)(1)):

 

Day

  

Liquidated Damage Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

L-1


[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

III.

Performance Delay Liquidated Damages (Clause 25.3(b)(i)(x)(1)):

 

Day

  

Liquidated Damage Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

L-2


[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

IV.

Performance Delay Liquidated Damages (Clause 25.3(b)(i)(y)(1)):

 

Day

  

Liquidated Damage Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

L-3


I.

Performance Delay Liquidated Damages (Clause 25.3(b)(ii)(1)):

 

Day

  

Liquidated Damage Amount

  

Liquidated Damage

Amount (in aggregate)

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

[***]

   [***]    [***]

 

L-4


APPENDIX M

CONTRACT PRICE ADJUSTMENTS

Part 1

The Contract Price shall be adjusted by the following adjustment index formula, provided that such adjustment shall (a) not be subject to any compounding and (b) be limited to a maximum reduction of [***], and maximum increase of [***], per annum:

[***]

where:

 

   

P1 = Calculated escalated Contract Price

 

   

PO = Original Contract Price

 

   

Index 1 = applicable index for the month of issuance of LNTP, or FNTP if LNTP is not issued,

 

   

Index 0 = applicable base index for the month of the Effective Date

and:

[***]

 

M-1


[***]

Part 2

The Contract Price shall be adjusted for foreign exchange as follows:

 

(i)

An amount in US Dollars equal to [***] of the Contract Price shall be converted from US Dollars into Euro at the exchange rate for US Dollars to Euro as of the Effective Date, which is stipulated to be [***] US Dollars to [***] Euro.

 

(ii)

The Euro amount determined pursuant to clause (i) shall be re-converted to US Dollars on the day of issuance of LNTP, or FNTP if LNTP is not issued, using the Euro reference exchange rate for the US Dollar published by the European Central Bank at link https://www.ecb.europa.eu/stats/policy and exchange rates/euro reference exchange rates/ html/index.en.html as determined by the Parties.

 

(iii)

An amount in US Dollars equal to [***] of the Contract Price shall be subtracted from the re-converted US Dollar amount determined pursuant to clause (iii).

 

(iv)

If the amount determined pursuant to clause (iii) is positive, it shall be added to the Contract Price by Change Order. If the amount determined pursuant to clause (iii) is negative, it shall be deducted from the Contract Price by Change Order.

Part 3

The Contract Price shall be further adjusted by the following adjustment index formula, provided that such adjustment shall (a) not be subject to any compounding and (b) be limited to a maximum reduction of [***], and maximum increase of [***], per annum:

[***]

 

M-2


where:

 

   

P1 = Calculated escalated Contract Price

 

   

PO = Original Contract Price for LTS Purchase Order

 

   

Index 1 = applicable index for the month of issuance of FNTP

 

   

Index 0 = applicable base index for the month that is [***] months after issuance of LNTP

and:

[***]

 

M-3


If the amount determined pursuant to this Part 3 is positive, it shall be added to the Contract Price by Change Order. If the amount determined pursuant to this Part 3 is negative, no amount shall be deducted from the Contract Price.

Part 4

The Contract Price shall be adjusted for foreign exchange as follows:

 

(i)

An amount in US Dollars equal to [***] of the Contract Price shall be converted from US Dollars into Euro at the exchange rate for US Dollars to Euro as of the LNTP issuance date.

 

(ii)

The Euro amount determined pursuant to clause (i) shall be re-converted to US Dollars on the day of issuance of FNTP, using the Euro reference exchange rate for the US Dollar published by the European Central Bank at link

  https://www.ecb.europa.eu/stats/policy and exchange rates/euro reference exchange rates/ html/index.en.html as determined by the Parties.

 

(iii)

An amount in US Dollars equal to [***] of the Contract Price shall be subtracted from the re-converted US Dollar amount determined pursuant to clause (iii).

If the amount determined pursuant to clause (iii) is positive, it shall be added to the Contract Price by Change Order. If the amount determined pursuant to clause (iii) is negative, no amount shall be deducted from the Contract Price by Change Order.

 

M-4

Exhibit 10.46

Certain identified information has been omitted from this document because (i) it is not material and is the type the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy, and has been marked with “[***]” to in indicate where omissions have been made.

CHANGE ORDER NO. 01

UNDER THE PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

August 8, 2024

Reference is made to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of April 7, 2023 (as amended, the “Agreement”), by and between Venture Global CP2 LNG, LLC, a Delaware limited liability company (“Buyer”) and Baker Hughes Energy Services LLC, a Delaware limited liability company (“Seller”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, including any adjustment to the Contract Price and/or the Project Schedule set forth herein, as applicable, has been agreed upon by the Parties in accordance with Clause 24 of Appendix A (General Terms & Conditions) of the Agreement, and is considered an amendment to the Agreement. Except to the extent as may be specifically described in this Change Order, the changes set forth herein do not relieve Seller of any of its responsibilities described in the Agreement.

Once this Change Order is executed by both Parties, and except to the extent set forth herein, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Seller fully for all such effects.

TERMS AND CONDITIONS:

Buyer and Seller further agree to the following changes to the Agreement:

 

1.

The defined term “Delivery Date” in Clause 1.1 of Appendix A (General Terms & Conditions) of the Agreement is hereby deleted in its entirety and the following is inserted in its place:

““Delivery Date” means, for each Liquefaction Train or Deliverable, the date on which such Liquefaction Train or Deliverable, as applicable, is required to be delivered by Seller to Buyer (pursuant to the Incoterms of the Agreement) in accordance with the Agreement, as further described in the Project Schedule.”

 

2.

Clause 6.4 (a) of Appendix A (General Terms & Conditions) of the Agreement is hereby deleted in its entirety and the following is inserted in its place:

“6.4 (a) Each Liquefaction Train and certain Deliverables have a Delivery Date. If Seller fails to deliver a Liquefaction Train or such Deliverable by its associated Delivery Date, as the Delivery Date may be extended according to a Change Order, Seller shall be obligated to pay to Buyer liquidated damages (the “Delivery Delay Liquidated Damages”) for delay in achieving the Delivery Date as from the first Day following the scheduled Delivery Date until the Day on which delivery of (i) that specific Liquefaction Train to the Delivery Point actually occurs, provided that Seller shall not be obligated to pay Delivery Delay Liquidated Damages for any Day (or part thereof) beyond [***] that is required for a Liquefaction Train to clear customs in the Country for reasons that are not attributable to Seller’s or its Subcontractors’ acts or omissions or (ii) that specific Deliverable to Buyer actually occurs.”


Execution Version

 

3.

Clause 6.4 (c) of Appendix A (General Terms & Conditions) of the Agreement is hereby deleted in its entirety and the following is inserted in its place:

“6.4 (c) For each Liquefaction Train, the liquidated damages payable by Seller to Buyer for each Day of delay in delivery of the specific Liquefaction Train (in its entirety) to the Delivery Point beyond the Delivery Date is (i) in respect of the first [***] Liquefaction Trains to be delivered, an amount equal to: (1) for each of the first [***] Days of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days; (ii) in respect of the subsequent [***] Liquefaction Trains, an amount equal to: (1) for each of the first [***] Days of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days.”

 

4.

Clause 6.4 (d) of Appendix A (General Terms & Conditions) of the Agreement is hereby deleted in its entirety and the following is inserted in its place:

“6.4 (d) The aggregate amount of Delivery Delay Liquidated Damages payable by Seller to Buyer for (i) each Liquefaction Train shall not exceed the applicable Delivery Delay Liquidated Damages Cap, and (ii) all Liquefaction Trains shall not exceed the Aggregate Delivery Delay Liquidated Damages Cap. Liquidated Damages payable by Seller to Buyer shall not exceed the Liquidated Damages Cap. Once Seller has accrued Delivery Delay Liquidated Damages in an amount equal to the Delivery Delay Liquidated Damages Cap or Aggregate Delivery Delay Liquidated Damages Cap, as applicable, Buyer shall be entitled to exercise the rights provided in Clause 6.5.”

 

5.

The first paragraph of Clause 6.7 of Appendix A (General Terms & Conditions) of the Agreement is hereby deleted in its entirety and the following is inserted in its place:

“If Seller delivers a Liquefaction Train (including for the avoidance of doubt, its associated Cold Box and E-House) to Buyer at the Delivery Point on or before the applicable bonus date set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (each, a “Bonus Date”) for such Liquefaction Train, then Buyer shall pay to Seller the applicable bonus amount set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) for each such Liquefaction Train; provided that each of such bonus amounts shall upon payment by Buyer be treated as an increase to the Contract Price for the purposes of the Agreement. If Seller delivers a Liquefaction Train (including for the avoidance of doubt, its associated Cold Box and E-House) before the applicable Delivery Date but after the applicable Bonus Date, the amount payable to Seller in respect of such Liquefaction Train shall be reduced by an amount equal to the applicable amount set forth Annex C-1 of


Execution Version

 

Appendix C (Scope of Supply & Project Schedule) (in each case, the “Degradation Factor”) multiplied by the number of days from the Bonus Date to the later of the actual date of delivery of such Liquefaction Train to the Delivery Point. If any of the Liquefaction Trains (including for the avoidance of doubt, the associated Cold Boxes or the associated E-Houses) is not delivered to the Delivery Point in its entirety on or before the applicable Delivery Date, then no bonus amount shall be earned or due.”

 

6.

Clause 25.3 of Appendix A (General Terms & Conditions) of the Agreement is hereby amended as follows:

 

  a.

Clause 25.3(a)(i) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***]” in its entirety and inserting “[***]” in its place.

 

  b.

Clause 25.3(a)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***]” in its entirety and insertin “[***]” in its place

 

  c.

Clause 25.3(b)(i) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to “[***]” in its entirety and inserting “[***]” in its place, and (ii) deleting the reference therein to “[***]” in its entirety and inserting “[***]” in its place.

 

  d.

Clause 25.3(b)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to “[***]” in its entirety and inserting “[***]” in its place.

SCOPE:

This Change Order modifies Appendix C (Scope of Supply & Project Schedule) as set forth below:

 

1.

Section 1.2 (Description of the Liquefaction Train sub-systems) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following bullet point after the last bullet point in the sub-section entitled “Cold Box Equipment”:

[***]


Execution Version

 

2.

Section 1.3 (Electrical System Scope) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet point immediately after the last bullet point of the section:

[***]


Execution Version

 

Seller shall modify the existing control architecture to incorporate the integration as follows:

[***]


Execution Version

 

3.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet point immediately after the last bullet point of the subsection “Others”:

[***]

 

4.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet point immediately after the last bullet point of the subsection “Others”:

[***]


Execution Version

 

5.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last sentence in the subsection titled “Instrumentation & Control”:

[***]

 

6.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last sentence in the subsection titled, “Structures and accessories”:

[***]


Execution Version

 

7.

Section 1.10 (Equipment and Components Preservation) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following immediately after the last paragraph:

[***]


Execution Version

 

8.

Section 1.2.2 (Mixed Refrigerant) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet points immediately after the last bullet point in the subsection entitled, “Lube Oil System”:

[***]

 

9.

Section 1.2.2 (Mixed Refrigerant) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last bullet point in the subsection entitled, “Air-Cooled Heat Exchangers (mounted on Modules)”:

[***]

 

10.

Section 1.2.2 (Mixed Refrigerant) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet points immediately after the last sentence of the section:

[***]


Execution Version

 

11.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following bullet points immediately after the last paragraph:

[***]


Execution Version

 

12.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last sentence in the subsection entitled, “Others”:

[***]


Execution Version

 

13.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting a new bullet point immediately after the last sentence in the subsection entitled, “Utilities”:

[***]

In accordance with Article 24 of the Agreement, Buyer and Seller have agreed to an adjustment to the Contract Price (on a lump sum basis) relating to the utility stations modifications.

 

14.

LM2500 and PGT25+ DLE Credit

Buyer and Seller have agreed to a reduction to the Contract Price (on a lump sum basis) in the amount of [***] in full, final and complete satisfaction of the purchase by Buyer or its Affiliates of certain compression station equipment consisting of [***] and [***].

 

15.

Foreign Exchange True-Up

In accordance with Part 2 of Appendix M (Contract Price Adjustments) to the Agreement, Buyer and Seller agree to an adjustment to the Contract Price (on a lump sum basis) relating to the date of issuance ofLNTP in full, final and complete satisfaction of Clause 7.1(B) of the Appendix A to the Agreement.

 

16.

Payment Schedule; Aggregate Payment Milestone Caps; Maximum Termination Fee Attached as Exhibit A to this Change Order is a revised version of Appendix B (Pricing; Payment Terms & Cancellation Schedule), which supersedes and replaces the existing Appendix B (Pricing; Payment Terms & Cancellation Schedule) in its entirety.

PROJECT SCHEDULE:

This Change Order modifies Annex C-1 (LTS Project Schedule) of Appendix C (Scope of Supply & Project Schedule) to the Agreement. Attached as Exhibit B to this Change Order is a revised version of Annex C-1 (LTS Project Schedule) of Appendix C (Scope of Supply & Project Schedule) to the Agreement, which supersedes and replaces the existing Annex C-1 (LTS Project Schedule) of Appendix C (Scope of Supply & Project Schedule) to the Agreement.


Execution Version

 

This Change Order shall have no impact on the Project Schedule or the Milestone dates, except as set forth in Exhibit B of this Change Order.

COST DETAILS

Attached hereto as Exhibit C to this Change Order contains the Seller’s cost details for the scope of supply modifications set forth herein for information purposes only.

 

CONTRACT PRICE:   

The original Contract Price was:

   $ [***]  

The net adjustment to the Contract Price by previously executed Change Orders is:

   $ [***]  

The Contract Price prior to this Change Order was:

   $ [***]  

The Contract Price shall be increased by this Change Order in the amount (the “Change Order Price”) of:

   $ [***]  
(comprised of: (1) a fixed lump sum amount of $[***], with respect to the changes set forth in Scope item 1 above (PCO#ll1B Rev 00 and PCO#115 Rev 01), (2) a fixed lump sum amount of $[***], with respect to the change set forth in Scope item 2 above (PCO#87 Rev 00, PCO#100 Rev 01, PCO#102 Rev 01, PCO#104 Rev 00 and PCO#114 Rev 00); (3) a fixed lump sum amount of $[***] with respect to the change set forth in Scope item 3 above (PCO#81 Rev 01); (4) a fixed lump sum amount of $[***] with respect to the changes set forth in Scope item 4 above (PCO#110 Rev 00) and PCO#111 Rev 00); (5) a fixed lump sum amount of $[***] with respect to the change set forth in Scope item 5 above (PCO#82 Rev 03); (6) a fixed lump sum in the amount of $[***] with respect to the change set forth in Scope item 6 above (PCO#91 Rev 01); (7) a fixed lump sum amount of $[***] with respect to the change set forth in Scope item 7 above (PCOs #88 Rev. 00); (8) a fixed lump sum amount of $[***] with respect to the change set forth in Scope item 8 above (PCO #64 Rev 00); (9) a fixed lump sum amount of $[***] with respect to the change set forth in Scope item 9 above (PCO#83 Rev 01); (10) a fixed lump sum amount of $[***] with respect to the change set forth in Scope item 10 above (PCO#78 Rev 03); (11) a fixed lump sum amount of $[***] with respect to the change set forth in Scope item 11 above (PCO#89 Rev 00); (12) a fixed lump sum amount of $[***] with respect to the changes set forth in Scope item 12 above (PCO#67 Rev 02, PCO#68 Rev 02, PCO#90 Rev 00, PCO#92 Rev 00, PCO#94 Rev 00,   


Execution Version

 

PCO#112 Rev 00 and PCO#108 Rev 00); (13) a fixed lump sum amount of $[***] with respect to the change set forth in Scope item 13 above (PCO#75 Rev 01); (14) less a fixed lump sum amount of $[***] with respect to the change set forth in Scope item 14 above; and (15) a fixed lump sum amount of $[***] with respect to the change set forth in Scope item 15 above).

  

The adjusted Contract Price, including this Change Order, shall be:

   $ [***]  

The original fixed fee for transportation was:

   $ [***]  

The net adjustment to the fixed fee by previously executed Change Orders is:

   $ [***]  

The fixed fee prior to this Change Order was:

   $ [***]  

The fixed fee shall be increased by this Change Order in the amount of:

   $ [***]  

The adjusted fixed fee for transportation, including this Change Order, shall be:

   $ [***]  

The original not to exceed amount for Transportation Costs was:

   $ [***]  

The net adjustment to the not to exceed amount for Transportation Costs by previously executed Change Orders is:

   $ [***]  

The adjusted not to exceed amount for Transportation Costs prior to this change order was:

   $ [***]  

The not to exceed amount for Transportation Costs shall be increased by this Change Order in the amount of:

   $ [***]  

The adjusted not to exceed amount for Transportation Costs, including this Change Order, shall be:

   $ [***]  


Execution Version

 

Seller waives any and all rights to claim any payment or any relief for time for the performance of its obligations for the performance of the scope of the changes that are set forth under this Change Order. This Change Order constitutes compensation in full for Seller for all costs and expenses directly or indirectly attributable to the changes set forth herein, for all delays related thereto, and for performance of the changes within the time stated. Notwithstanding, such adjusted Contract Price does not include any Buyer Taxes which will be added to such Contract Price in accordance with and subject to the terms of the Agreement.

All other terms and conditions of the Agreement remain in effect unless specifically modified herein.

[Signature Page Follows.]


Agreed pursuant to the Agreement by:

 

Baker Hughes Energy Services LLC

    Venture Global CP2 LNG, LLC
By:  

/s/ Chris Coffman

    By:  

/s/ Jonathan W. Thayer

Name:   Chris Coffman     Name:   Jonathan W. Thayer
Title:   Vice President     Title:   Chief Financial Officer


Execution Version

 

Exhibit A

APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one ( 1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement.

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders.

In addition to the amounts shown in the Payment Milestone in Section I.B., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] during the first [***] of the Payment Schedule following the issuance of FNTP and [***] during the [***] of the payment schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the Transportation Fixed Fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of [***]. In all other cases, Facility-specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Cameron Parish sales and use taxes that constitute Buyer Taxes. Any such Cameron Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.


Execution Version

 

I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of Pre-LNTP and/or LNTP shall be as indicated in the table below.

 

Type

  

Milestone

No

  

Payment Milestone Description

  

Amount

(USD)

[***]

   1    [***]    $[***]

[***]

   L1    [***]    $[***]

[***]

   2    [***]    $[***]

[***]

   3    [***]    $[***]

[***]

   4    [***]    $[***]

[***]

   5    [***]    $[***]

[***]

   6    [***]    $[***]


Execution Version

 

  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.

 

Type

  

Milestone

No

  

Milestone Description

  

Amount

(USD)

[***]

   1    [***]    $[***]

[***]

   L1    [***]    $[***]

[***]

   2    [***]    $[***]

[***]

   3    [***]    $[***]

[***]

   4    [***]    $[***]

[***]

   5    [***]    $[***]

[***]

   6    [***]    $[***]

[***]

   7    [***]    $[***]

[***]

   8    [***]    $[***]

[***]

   9    [***]    $[***]

[***]

   10    [***]    $[***]

[***]

   11    [***]    $[***]

[***]

   12    [***]    $[***]


Execution Version

 

[***]

   13    [***]    $[***]

[***l

   14    [***]    $[***]

[***]

   15    [***]    $[***]

[***1

   16    [***]    $[***]

[***]

   17    [***]    $[***]

[***]

   18    [***]    $[***]

[***]

   19    [***]    $[***]

[***l

   20    [***]    $[***]

[***]

   21    [***]    $[***]

[***1

   22    [***]    $[***]

[***]

   23    [***]    $[***]

[***]

   24    [***]    $[***]

[***]

   25    [***]    $[***]

[***]

   26    [***]    $[***]

[***]

   27    [***]    $[***]

[***l

   28    [***]    $[***]

[***]

   29    [***]    $[***]

[***]

   30    [***]    $[***]

[***]

   31    [***]    $[***]

[***]

   32    [***]    $[***]

[***]

   33    [***]    $[***]

[***]

   34    [***]    $[***]


Execution Version

 

Payment Milestone Notes

1

   [***]

2

   [***]

3

   [***]

4

   [***]

5

   [***]

6

   [***]

7

   [***]

8

   [***]

9

   [***]


Execution Version

 

Payment Milestone Notes

10

   [***]

11

   [***]


Execution Version

 

Payment Milestone Notes

12

   [***]

13

   [***]

14

   [***].

 

II.

Aggregate Payment Milestone Cap:

The aggregate amount of all Payment Milestones invoiced by Seller as of each month, including all invoices submitted to Buyer in prior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month.

 

  A.

[***]

 

Month after Issuance of Pre-LNTP

or LNTP

  

Aggregate Payment Milestone Cap (by month)

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]

[***]

   $[***]


Execution Version

 

  B.

[***]

 

Month after Issuance of Pre-LNTP

or LNTP or FNTP, as

applicable

  

Aggregate Payment Milestone Cap (by month)

after CO#1

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]


Execution Version

 

Month after Issuance of Pre-LNTP

or LNTP or FNTP, as

applicable

  

Aggregate Payment Milestone Cap (by month)
after CO#l

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]


Execution Version

 

III.

Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29.1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]

where:

[***]

 

Months after issuance of Pre-LNTP,

LNTP or issuance of a Suspension

Notice, as Applicable

  

Maximum Termination Fee after CO#l

[***]

   $[***]

[***]

   $[***]


Execution Version

 

Months after issuance of Pre-LNTP,

LNTP or issuance of a Suspension

Notice, as Applicable

  

Maximum Termination Fee after CO#l

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

 

4.

If LNTP is issued and FNTP is subsequently issued prior to the termination of the Agreement, the Maximum Termination Fee shall be as follows; provided, however, that if (a) no LNTP is issued but the FNTP is issued or (b) FNTP is issued less than [***] days after the issuance of LNTP, in either case, the Maximum Termination Fee set forth in the first [***] months in the table below shall be increased by [***].

 

Months after issuance of

Pre-LNTP, LNTP

or issuance of a Suspension

Notice, as Applicable

  

Maximum Termination Fee after CO#l

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]


Execution Version

 

Months after issuance of

Pre-LNTP, LNTP

or issuance of a Suspension

Notice, as Applicable

  

Maximum Termination Fee after CO#l

[***]

   $[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]

[***]

  

$[***]


Execution Version

 

Exhibit B

Annex C-1

LTS Project Schedule

[Omitted]


Execution Version

 

Exhibit C

Cost Details

[Omitted]

Execution Version

Exhibit 10.47

CERTAIN IDENTIFIED INFORMATION HAS BEEN OMITTED FROM THIS DOCUMENT BECAUSE (I) IT IS NOT MATERIAL AND IS THE TYPE THAT THE COMPANY CUSTOMARILY AND ACTUALLY TREATS AS PRIVATE OR CONFIDENTIAL, AND/OR (II) IF DISCLOSURE WOULD CONSTITUTE A CLEARLY UNWARRANTED INVASION OF PERSONAL PRIVACY, AND HAS BEEN MARKED WITH “[***]” TO IN INDICATE WHERE OMISSIONS HAVE BEEN MADE.

CHANGE ORDER NO. 02

UNDER THE PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

November 15, 2024

Reference is made to the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of April 7, 2023 (as amended, the “Agreement”), by and between Venture Global CP2 LNG, LLC, a Delaware limited liability company (“Buyer”) and Baker Hughes Energy Services LLC, a Delaware limited liability company (“Seller”). Capitalized terms used but not defined herein shall have the meanings set forth in the Agreement. This Change Order, including any adjustment to the Contract Price and/or the Project Schedule set forth herein, as applicable, has been agreed upon by the Parties in accordance with Clause 24 of Appendix A (General Terms & Conditions) of the Agreement, and is considered an amendment to the Agreement. Except to the extent as may be specifically described in this Change Order, the changes set forth herein do not relieve Seller of any of its responsibilities described in the Agreement.

Once this Change Order is executed by both Parties, and except to the extent set forth herein, this Change Order will constitute a full and final settlement and accord and satisfaction of all effects of the change(s) described herein, and shall be deemed to compensate Seller fully for all such effects.

TERMS AND CONDITIONS:

Buyer and Seller further agree to the following changes to the Agreement:

 

  1.

Clause 6.4 (c) of Appendix A (General Terms & Conditions) of the Agreement is hereby deleted in its entirety and the following is inserted in its place:

“6.4 (c) For each Liquefaction Train, the liquidated damages payable by Seller to Buyer for each Day of delay in delivery of the specific Liquefaction Train (in its entirety) to the Delivery Point beyond the Delivery Date is (i) in respect of the first [***] Liquefaction Trains to be delivered, an amount equal to: (1) for each of the first [***] Days of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days; (ii) in respect of the subsequent [***] Liquefaction Trains, an amount equal to: (1) for each of the first [***] Days of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days.”

 

1


  2.

Clause 25.3 of Appendix A (General Terms & Conditions) of the Agreement is hereby amended as follows:

 

  a.

Clause 25.3(a)(i) of Appendix A to the Agreement is hereby amended by deleting the reference therein to [***] in its entirety and inserting [***] in its place.

 

  b.

Clause 25.3(a)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to [***] in its entirety and inserting [***] in its place.

 

  c.

Clause 25.3(b)(i) of Appendix A to the Agreement is hereby amended by (i) deleting the reference therein to [***] in its entirety and inserting [***] in its place, and (ii) deleting the reference therein to [***] in its entirety and inserting [***] in its place.

 

  d.

Clause 25.3(b)(ii) of Appendix A to the Agreement is hereby amended by deleting the reference therein to [***] in its entirety and inserting [***] in its place.

SCOPE:

This Change Order modifies Appendix C (Scope of Supply & Project Schedule) as set forth below:

 

  1.

Section 1.2.1 (Feed Gas Liquefaction) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following bullet points after the last bullet point in the sub-section entitled “Cold Box Equipment”:

[***]

 

  2.

Section 1.5 (Scope Clarifications) of Appendix C (Scope of Supply & Project Schedule) to the Agreement is hereby amended by inserting the following new bullet points immediately after the last bullet point of the subsection entitled “Others”:

[***]

APPENDIX B:

Attached as Exhibit A to this Change Order is a revised version of Appendix B (Pricing; Payment Terms & Cancellation Schedule), which supersedes and replaces the existing Appendix B (Pricing; Payment Terms & Cancellation Schedule) in its entirety.

PROJECT SCHEDULE:

This Change Order shall have no impact on the Project Schedule or the Milestone dates.

 

2


COST DETAILS

Attached hereto as Exhibit B to this Change Order contains the Seller’s cost details for the scope of supply modifications set forth herein for information purposes only.

CONTRACT PRICE:

 

The original Contract Price was:

   $ [ ***] 

The net adjustment to the Contract Price by previously executed Change Orders is:

   $ [ ***] 

The Contract Price prior to this Change Order was:

   $ [ ***] 

The Contract Price shall be increased by this Change Order in the amount (the “Change Order Price”) of:

   $ [ ***] 

(comprised of:

  

(1) a fixed lump sum amount of $[***], with respect to the changes set forth in Scope item 1 above (PCO#61B Rev 02), and

  

(2) a fixed lump sum amount of $[***], with respect to the change set forth in Scope item 2 above (PCO#113 Rev 02, PCO#120 Rev 01, PCO#121 Rev 01, PCO#117 Rev 02, PCO#118 Rev 03, PCO#119 Rev 02, and PCO#126 Rev 00).

  

The adjusted Contract Price, including this Change Order, shall be:

   $ [ ***] 

The original fixed fee for transportation was:

   $ [ ***] 

The net adjustment to the fixed fee by previously executed Change Orders is:

   $ [ ***] 

The fixed fee prior to this Change Order was:

   $ [ ***] 

The fixed fee shall be increased by this Change Order in the amount of:

   $ [ ***] 

The adjusted fixed fee for transportation, including this Change Order, shall be:

   $ [ ***] 

The original not to exceed amount for Transportation Costs was:

   $ [ ***] 

 

3


The net adjustment to the not to exceed amount for Transportation Costs by previously executed Change Orders is:

   $ [ ***] 

The adjusted not to exceed amount for Transportation Costs prior to this change order was:

   $ [ ***] 

The not to exceed amount for Transportation Costs shall be increased by this Change Order in the amount of:

   $ [ ***] 

The adjusted not to exceed amount for Transportation Costs, including this Change Order, shall be:

   $ [ ***] 

Seller waives any and all rights to claim any payment or any relief for time for the performance of its obligations for the performance of the scope of the changes that are set forth under this Change Order. This Change Order constitutes compensation in full for Seller for all costs and expenses directly or indirectly attributable to the changes set forth herein, for all delays related thereto, and for performance of the changes within the time stated. Notwithstanding, such adjusted Contract Price does not include any Buyer Taxes which will be added to such Contract Price in accordance with and subject to the terms of the Agreement.

All other terms and conditions of the Agreement remain in effect unless specifically modified herein.

[Signature Page Follows.]

 

4


Agreed pursuant to the Agreement by:    
Baker Hughes Energy Services LLC     Venture Global CP2 LNG, LLC
By:   /s/ Chris Coffman     By:   /s/ Jonathan W. Thayer
Name:   Chris Coffman     Name:   Jonathan W. Thayer
Title:   Vice President     Title:   Chief Financial Officer

 

5


Exhibit A

APPENDIX B

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one (1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement.

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders. 

In addition to the amounts shown in the Payment Milestone in Section I.B., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] during the first [***] of the Payment Schedule following the issuance of FNTP and [***] during the [***] month of the payment schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the Transportation Fixed Fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of $[***]. In all other cases, Facility-specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Cameron Parish sales and use taxes that constitute Buyer Taxes. Any such Cameron Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.

 

6


I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of Pre-LNTP and/or LNTP shall be as indicated in the table below.

 

Type

   Milestone
   Payment Milestone Description   Amount
(USD)
 

[***]

   1    [***]   $ [***]  

[***]

   L1    [***]   $ [***]  

[***]

   2    [***]   $ [***]  

[***]

   3    [***]   $ [***]  

[***]

   4    [***]   $ [***]  

[***]

   5    [***]   $ [***]  

[***]

   6    [***]   $ [***]  

 

  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.

 

Type

   Milestone
   Milestone Description   Amount
(USD)
 

[***]

   1    [***]   $ [***]  

[***]

   L1    [***]   $ [***]  

[***]

   2    [***]   $ [***]  

[***]

   3    [***]   $ [***]  

[***]

   4    [***]   $ [***]  

[***]

   5    [***]   $ [***]  

[***]

   6    [***]   $ [***]  

[***]

   7    [***]   $ [***]  

[***]

   8    [***]   $ [***]  

[***]

   9    [***]   $ [***]  

 

7


[***]

   10    [***]   $ [***]  

[***]

   11    [***]   $ [***]  

[***]

   12    [***]   $ [***]  

[***]

   13    [***]   $ [***]  

[***]

   14    [***]   $ [***]  

[***]

   15    [***]   $ [***]  

[***]

   16    [***]   $ [***]  

[***]

   17    [***]   $ [***]  

[***]

   18    [***]   $ [***]  

[***]

   19    [***]   $ [***]  

[***]

   20    [***]   $ [***]  

[***]

   21    [***]   $ [***]  

[***]

   22    [***]   $ [***]  

[***]

   23    [***]   $ [***]  

[***]

   24    [***]   $ [***]  

[***]

   25    [***]   $ [***]  

[***]

   26    [***]   $ [***]  

[***]

   27    [***]   $ [***]  

[***]

   28    [***]   $ [***]  

[***]

   29    [***]   $ [***]  

[***]

   30    [***]   $ [***]  

[***]

   31    [***]   $ [***]  

[***]

   32    [***]   $ [***]  

[***]

   33    [***]   $ [***]  

[***]

   34    [***]   $ [***]  

[***]

   35    [***]   $ [***]  

[***]

   36    [***]   $ [***]  

[***]

   37    [***]   $ [***]  

[***]

   38    [***]   $ [***]  

 

Payment Milestone Notes

 

1

     [***]  

2

     [***]  

3

     [***]  

4

     [***]  

5

     [***]  

6

     [***]  

7

     [***]  

 

8


Payment Milestone Notes

 

8

     [***]  

9

     [***]  

10

     [***]  

11

     [***]  

12

     [***]  

13

     [***]  

14

     [***]  

 

II.

Aggregate Payment Milestone Cap:

The aggregate amount of all Payment Milestones invoiced by Seller as of each month, including all invoices submitted to Buyer in prior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month.

 

  A.

[***]

 

Month after Issuance of Pre-LNTP

or LNTP

   Aggregate Payment Milestone Cap (by month)  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

 

9


  B.

[***]

 

Month after Issuance of Pre-

LNTP or LNTP or FNTP, as

applicable

   Aggregate Payment Milestone Cap (by month)
after CO#2
 

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

 

10


Month after Issuance of Pre-

LNTP or LNTP or FNTP, as

applicable

   Aggregate Payment Milestone Cap (by month)
after CO#2
 

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

 

11


III.

Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29.1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]

where:

[***]

 

Months after issuance of Pre-LNTP,

LNTP or issuance of a Suspension

Notice, as Applicable

   Maximum Termination Fee after CO#2  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

4. [***]

 

Months after issuance of

Pre-LNTP, LNTP or FNTP

or issuance of a Suspension

Notice, as applicable

   Maximum Termination Fee after CO#2  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

[***]

   $ [***]  

 

12


Months after issuance of

Pre-LNTP, LNTP or FNTP

or issuance of a Suspension

Notice, as applicable

   Maximum Termination Fee after CO#2  

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

[***]

   $ [ ***] 

 

13


Exhibit B

Cost Details

[Omitted]

 

14

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Exhibit 10.48

Execution Version

PURCHASE ORDER CONTRACT

FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM

THIS PURCHASE ORDER CONTRACT FOR THE SALE OF LIQUEFACTION TRAIN SYSTEM (hereinafter this “Agreement”) is entered into as of December 13, 2024 (the “Effective Date”) by and between BAKER HUGHES ENERGY SERVICES LLC, a limited liability company organized and existing under the laws of the State of Delaware, with an address and place of business at 575 N. Dairy Ashford, Suite 100, Houston, Texas 77079 (hereinafter the “Seller”), and VENTURE GLOBAL CP2 LNG, LLC, a limited liability company organized and existing under the laws of the State of Delaware, with an address at 1401 McKinney Street, Suite 2600, Houston, TX 77010 (hereinafter the “Buyer”).

The Buyer and the Seller are referred to herein individually as a “Party” and collectively as the “Parties”.

RECITALS

WHEREAS, Buyer intends to develop, construct and operate a liquefied natural gas (“LNG”) export facility and terminal on a site adjacent to the Calcasieu Ship Channel, in Cameron Parish, Louisiana, south of Lake Charles, Louisiana, U.S.A. (as defined in Appendix A (General Terms & Conditions));

WHEREAS, Seller designs, engineers, fabricates and manufactures certain natural gas liquefaction equipment in Seller’s affiliated manufacturing facilities;

WHEREAS, Seller sells Liquefaction Train Systems, as defined in Appendix A (General Terms & Conditions);

WHEREAS, Buyer desires to purchase the Liquefaction Train System from Seller for deployment at the Facility, under the terms and conditions set forth herein;

WHEREAS, Buyer and Seller entered into that certain Purchase Order Contract for the Sale of Liquefaction Train System, dated as of April 7, 2023, in relation to the sale of a liquefaction train system described therein to Buyer with respect to the initial phase of the LNG export terminal and liquefaction project to be located at the Site (the “Initial LTS Purchase Order”);

WHEREAS, Buyer and Seller entered into that certain Purchase Order Contract for the Sale of Power Island System, dated as of September 30, 2024, in relation to the sale of a power island system described therein to Buyer (the “PIS Purchase Order”); and

WHEREAS, Seller is providing, subject to the terms and conditions of this Agreement, an Unconditional Performance Obligation (as defined herein) with production and efficiency standards for the Liquefaction Train System forming part of the process system of the Facility.

NOW, THEREFORE, in consideration of these Recitals, the mutual covenants, promises and agreements contained herein, and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound, the Parties agree as follows:


1.

SCOPE OF SUPPLY

Seller agrees to manufacture, sell and deliver the Liquefaction Train System to Buyer as set forth in Appendix C (Scope of Supply & Project Schedule) to this Agreement.

 

2.

PRICE AND PAYMENT

In consideration of the supply of a Liquefaction Train System as described in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule), the Buyer will pay to the Seller the contract price in the increments and on the payment schedule as specified in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule). Termination and cancellation charges shall be as specified in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule).

 

3.

PERIOD OF PERFORMANCE

Seller shall complete the performance of all of its obligations set forth in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule) in accordance with the activity completion and delivery schedule described in Appendix C (Scope of Supply & Project Schedule) and the terms of this Agreement. The Liquefaction Train System shall be delivered subject to the Incoterms 2020 as described in Appendix A (General Terms & Conditions) and Appendix C (Scope of Supply & Project Schedule). Buyer shall complete performance of all of its obligations set forth in Appendix A (General Terms & Conditions) and Appendix B (Pricing; Payment Terms & Cancellation Schedule) in accordance with the terms of this Agreement.

 

4.

TERMS AND CONDITIONS

The following terms and conditions are applicable to this Agreement. The Agreement between the Parties shall be comprised of and consists of the following documents (the “Order Documents”), each of which shall be read and construed as an integral part of the Agreement, listed in order of precedence in case of dispute:

 

1.    This document;
2.    Appendix A:    General Terms & Conditions;
3.    Appendix B:    Pricing; Payment Terms & Cancellation Schedule;
4.    Appendix C:    Scope of Supply & Project Schedule;
5.    Appendix D:    Form of Buyer Parent Company Guarantee;
6.    Appendix E:    Quality Assurance and Quality Control;
7.    Appendix F:    Performance Tests;
8.    Appendix G:    Approved Subcontractors;

 

2


9.    Appendix H:    Form of Seller Parent Company Guarantee
10.    Appendix I:    Form of Change Order;
11.    Appendix J:    Form of Lien Waivers and Releases;
   J-1    Seller Form of Partial Lien Waiver and Release;
   J-2    Seller Form of Final Lien Waiver and Release;
   J-3    Subcontractor Form of Partial Lien Waiver and Release;
   J-4    Subcontractor Form of Final Lien Waiver and Release;
12.    Appendix K:    Transportation Costs; and
13.    Appendix L:    Liquidated Damage Amounts.
14.    AppendixM:    Contract Price Adjustments

 

5.

LIMITED RECOURSE

Except to the extent as otherwise provided in any parent guarantee provided to Seller under this Agreement, in the event of non-performance by Buyer of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (a) any assets or properties of any of the shareholders, members or partners of the Buyer, (b) any Affiliate of Buyer or (c) any officers, directors or employees thereof, and no judgment relating to the obligations of Buyer under this Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of Buyer or any other officer, employee or director past, present or future of the Buyer or any of its shareholders, members, partners or Affiliates.

Except to the extent as otherwise provided in any parent guarantee provided to Buyer under this Agreement, in the event of non-performance by Seller of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (a) any assets or properties of any of the shareholders, members or partners of the Seller, (b) any Affiliate of Seller or (c) any officers, directors or employees thereof, and no judgment relating to the obligations of Seller under this Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of the Seller or any other officer, employee or director past, present or future of the Seller or any of its shareholders, members, partners or Affiliates.

 

6.

ENTIRE AGREEMENT

The Order Documents making up the Agreement, excluding for the avoidance of doubt that certain Fourth Amended and Restated Letter of Agreement, dated as of April 7, 2023, by and between Seller and Venture Global LNG, Inc. (as further amended, amended and restated, supplemented, or otherwise modified from time to time), together with the Initial L TS Purchase Order (as amended, amended and restated, supplemented, or otherwise modified from time to

 

3


time), constitute and represent the entire agreement between the Parties and supersede in their entirety any and all prior agreements or understandings concerning the subject matter hereof, and no modification, amendment, revision, waiver, or other change shall be binding on either Party unless consented to in writing by the Parties or their authorized representatives. Any oral or written representation, warranty, course of dealing or trade usage not contained or referenced herein shall not be binding on either Party. Each Party agrees that it has not relied on, or been induced by, any representations of the other Party not contained in this Agreement.

 

7.

GOVERNING LAW; DISPUTE RESOLUTION

This Agreement shall be subject to the dispute resolution and governing law provisions as further described in Clause 20 and Clause 21 of Appendix A (General Terms & Conditions).

 

8.

INTERPRETATION

Capitalized terms used in this Agreement that are not otherwise defined shall have the meaning given in Appendix A (General Terms & Conditions) and the rules of interpretation set forth in Clause 1.2 of Appendix A (General Terms & Conditions) shall apply to this Agreement.

[SIGNATURES APPEAR ON THE FOLLOWING PAGE]

 

4


IN WITNESS WHEREOF the Parties have caused this Agreement to be executed by their authorized representatives as of the Effective Date.

 

SELLER:     BUYER:
BAKER HUGHES ENERGY SERVICES LLC     VENTURE GLOBAL CP2 LNG, LLC
By:  

/s/ Edoardo Padeletti

    By:  

/s/ Jonathan W. Thayer

Name:   Edoardo Padeletti     Name:   Jonathan W. Thayer
Title:   VP Commercial & Strategy     Title:   Chief Financial Officer

[Signature Page to Purchase Order Contract for the Sale of Liquefaction Train System]


APPENDIX A

GENERAL TERMS & CONDITIONS

 

1.

DEFINITIONS AND INTERPRETATION

 

1.1

Definitions.

Unless otherwise defined elsewhere in the Agreement, the following terms shall have the following meanings:

“Affiliate” with respect to a Party means an entity (including without limitation any individual, corporation, partnership, limited liability company, association or trust) controlling, controlled by or under common control with that Party. As used herein, “control” means the possession, directly or indirectly, of the power to direct or cause the direction of the management of policies of such Party, whether through the ownership of voting securities or other interest, by contract or otherwise. For the avoidance of doubt, for the purposes of the Agreement, Venture Global Calcasieu Pass, LLC and Venture Global Plaquemines LNG, LLC shall not be deemed to be Affiliates of Buyer.

“Aggregate Delivery Delay Liquidated Damages Cap” means an amount equal to [***] of the Contract Price.

“Aggregate Performance Delay Liquidated Damages Cap” means an amount equal to [***] of the Contract Price.

“Anti-Corruption Laws” has the meaning given to it in Clause 16.5(b).

“Approved Subcontractors” means the Subcontractors listed under “Selected Subcontractors” in Appendix G (Approved Subcontractors) of the Agreement and that are otherwise proposed by Seller and approved by Buyer in accordance with Clause 4.2.

“Background Intellectual Property” means all Intellectual Property, relevant to the Agreement, that a Party created or acquired before the Effective Date or that a Party creates or acquires independently of the Agreement and not in the performance of its obligations hereunder.

“Bankruptcy Event” means, with respect to a Person, that such Person: (a) files a petition or otherwise commences, or authorizes the commencement of, a proceeding or cause under any bankruptcy, insolvency, receivership or similar law for the protection of creditors; (b) has such a petition filed or proceeding commenced against it, which remains undismissed for ninety (90) Days; (c) files an answer or pleading admitting or failing to contest the material allegations of any such petition; (d) takes any action for its winding up, liquidation or dissolution; (e) is otherwise adjudged bankrupt or insolvent under any bankruptcy, insolvency, receivership or similar law for the protection of creditors; or (f) consents to any of the actions described in clauses (a) through (e) of this definition being taken against it.

 

A-1


BAR Policy” has the meaning given to it in Clause 23.4.

Basis of Design” means the basis of design set forth in Appendix C (Scope of Supply & Project Schedule).

Benefitted Party” has the meaning given to it in Clause 8.2.

BH-Transient Liquefaction Train Simulation Model” has the meaning given to it in Clause 18.9.

Bonus Date” has the meaning given to it in Clause 6.7.

Bonus Degradation Factor” has the meaning given to it in Clause 6.7.

BHH” means Baker Hughes Holdings LLC, a Delaware limited liability company.

Buyer” has the meaning given to it in the preamble of the Agreement.

Buyer Developed Intellectual Property” has the meaning given to it in Clause 18.4.

Buyer Excluded Parties” means Buyer, Owner and each of their Affiliates, Venture Global Calcasieu Pass, LLC, Venture Global Plaquemines LNG, LLC and all other entities directly or indirectly owned by Venture Global LNG, Inc., and each of their subsidiaries, owners, shareholders and all of their respective directors, officers, assigns and employees, and the EPC Contractor (and EPC Contractor’s respective affiliates, subsidiaries, owners, shareholders and its respective directors, officers, assigns and employees).

Buyer Inspection Parties” means Buyer, Owner, Owner’s customers, Lenders, Lender’s Engineer and their respective representatives and agents.

Buyer Parent Company Guarantee” means the guarantee, in the form set out in Appendix D (Form of Buyer Parent Company Guaranty), to be issued by Buyer’s parent company and delivered by Buyer to Seller in accordance with Clause 7.8.

Buyer Parties” means Buyer, Owner, the Lenders and each of their Affiliates and all of their respective directors, officers, agents, advisors, engineers, contractors, consultants, representatives, assigns, employees and any other Person acting on behalf of any of them or in representation, interest, benefit thereto.

Buyer Taxes” means any and all existing or future taxes, Duties, fees, or other charges of any nature (including, but not limited to, ad valorem, consumption, excise, franchise, gross receipts, import, export, license, property, sales and use, stamp, storage, transfer, turnover, or value-added taxes, or other similar taxes, and any and all items of deficiency, penalty, addition to tax, interest, or assessment related thereto), imposed by any Governmental Authority of the United States of America (or any political subdivision thereof) in connection with the execution of the Agreement or the purchase of the Liquefaction Train System, but excluding Seller Taxes.

 

A-2


“Buyer’s Representatives” has the meaning given to it in Clause 22.1.

“Calcasieu Purchase Order” means the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of September 25, 2018, between Seller and Venture Global Calcasieu Pass, LLC.

“Change Order” has the meaning given to it in Clause 24.1.

“Cold Box” means the Liquefaction Train cold box, as further described in Appendix C (Scope of Supply & Project Schedule).

“Confidential Information” has the meaning given to it in Clause 22.1.

“Contract Price” means the aggregate amount stated in Clause 7.1 for the purchase of the Liquefaction Train System, as further described in Appendix B (Pricing; Payment Terms & Cancellation Schedule) and as such amount may be modified pursuant to a Change Order signed by Seller and Buyer in accordance with the requirements of the Agreement.

“Costs” means all reasonable and documented expenses, costs and third-party disbursements incurred by a Party, but excluding any such expenses, costs and disbursements that are excluded pursuant to Clause 19.3.

“Country” means the United States of America.

“Credit Rating” means the current (a) rating issued or maintained by S&P or Moody’s with respect to such entity’s long-term senior, unsecured, unsubordinated debt obligations (not supported by third party credit enhancements) or (b) corporate credit rating or long-term issuer rating issued or maintained with respect to such entity by S&P or Moody’s.

“Day” means a calendar day, i.e. any twenty-four (24) hour period beginning and ending at 12:00 midnight in the State of Louisiana, unless otherwise specified herein as starting from a specific hour.

“Defect” means a failure to meet any warranty set forth in Clause 17.1.

“Delay Limit Date” means the date on which Seller has accrued an aggregate amount of Delivery Delay Liquidated Damages in an amount equal to or greater than (a) the applicable Delivery Delay Liquidated Damages Cap, or (b) Aggregate Delivery Delay Liquidated Damages Cap.

“Delivery Delay Event” means each instance in which Seller fails to deliver a Liquefaction Train (in its entirety) or Deliverable, as applicable, by its associated Delivery Date.

Delivery Delay Liquidated Damages” has the meaning given to it in Clause 6.4(a).

“Delivery Delay Liquidated Damages Cap” means, in respect of each Liquefaction Train, an amount equal to (a) [***] of the Aggregate Delivery Delay Liquidated Damages Cap in respect of each of the first [***] Liquefaction Trains to be delivered, and (b) [***] of the Aggregate Delivery Delay Liquidated Damages Cap in respect of each of the subsequent [***] Liquefaction Trains to be delivered.

 

A-3


“Deliverables” means all information, including the Technical Documentation, that was first conceived, reduced to practice or created by Seller or its employees or Subcontractors in the performance of its obligations under the Agreement, a list of which is set forth in Appendix C (Scope of Supply & Project Schedule).

“Delivery Date” means, for each Liquefaction Train or Deliverable, as applicable, the date on which such Liquefaction Train or Deliverable, as applicable, is required to be delivered by Seller to Buyer (pursuant to the Incoterms of the Agreement) in accordance with the Agreement, as further described in the Project Schedule.

“Delivery Point” has the meaning given to it in Clause 9.1.

“Degradation Factor” has the meaning given to it in Clause 6.7.

“Disclosing Party” has the meaning given to it in Clause 22.1.

“Dispute” has the meaning given to it in Clause 20.1.

“Dollars” means the lawful currency of the United States of America.

“Duties” has the meaning given to it in Clause 7.1.

“EAR” has the meaning given to it in Clause 16.2.

“EDR File” has the meaning given to it in Clause 18.6.

“Effective Date” has the meaning given to it in the preamble of the Agreement.

“EPC Agreement” means the agreement that Owner enters into with one or more Persons for the construction of the Facility.

“EPC Contractor” means any Person (other than Owner) that is a party to the EPC Agreement. “Event of Default” means an event of default of Seller described in Clause 28.1 or an event of default of Buyer described in Clause 28.2, which in each case has not been cured within the applicable cure period, if any, as provided by the terms of such Clauses.

“Facility” means the LNG export terminal and liquefaction project to be located at the Site, including as such term is defined under the Initial LTS Purchase Order.

“Factory Acceptance Tests” has the meaning given to it in Clause 14.5.

 

A-4


Finance Agreements” means the agreements entered into or to be entered into between Owner or its Affiliates and the Lenders and the other documents related thereto for the purpose of providing financing, refinancing or other financial services for the Facility.

Financial Closing” means that all of the conditions precedent set forth in the Finance Agreements shall have been satisfied or waived and the Lenders party thereto have disbursed the initial loans thereunder.

FNTP” has the meaning given to it in Clause 6.6.

Force Majeure Event” has the meaning given to it in Clause 33.1.

Force Majeure Report” has the meaning given to it in Clause 33.4.

Governmental Authority” means any federal, state, regional, city or local government, any intergovernmental association or political subdivision thereof, or other governmental, regulatory or administrative agency, court, commission, administration, department, board, or other governmental subdivision, legislature, rulemaking board, tribunal or other governmental authority with jurisdiction over Seller, Seller Parties (as may be applicable), Buyer, Owner, EPC Contractor, the Liquefaction Train System(s) or any part thereof or the Site, or any Person acting as a delegate or agent of any Governmental Authority.

“Government Official” has the meaning given to it in Clause 16.5(c).

Guaranteed Liquefaction Train Substantial Completion Date” means, with respect to a Liquefaction Train, the last day of the Liquefaction Train Testing Period (as defined in Appendix F (Performance Tests)) for such Liquefaction Train, on which Substantial Completion of the Liquefaction Train for such Liquefaction Train is required to be achieved.

Guaranteed Liquefaction Train System Substantial Completion Date” means the last day of the Liquefaction Train System Testing Period (as defined in Appendix F (Performance Tests)), on which Substantial Completion of the Liquefaction Train System is required to be achieved.

Hazardous Materials” means any chemical, substance, material or emission, including H2S gas, that is or may be regulated, governed, listed or controlled pursuant to any international, national, federal, provincial, state or local statute, ordinance, order, directive, regulation, judicial decision or other legal requirement applicable to Site as a toxic substance, hazardous substance, hazardous material, dangerous or hazardous waste, dangerous good, pesticide, radioactive material, regulated substance or any similar classification, or any other chemical, substance, emission or material, including, without limitation, petroleum or petroleum-derived products or by-products, regulated, governed, listed or controlled or as to which liability is imposed on the basis of potential impact to safety, health or the environment pursuant to any rule or regulation promulgated by any Governmental Authority.

ICC Rules” has the meaning given to it in Clause 20.2.

 

A-5


Initial LTS Purchase Order” has the meaning given to it in the recitals of the Agreement.

Instruments of Service” has the meaning given to it in Clause 18.5.

Intellectual Property” means all intellectual property and proprietary rights thereto, including all rights of inventorship and authorship, inventions, patents, patent applications, patent disclosures, know-how, processes, methods, machines, manufactures, designs, compositions of matter, or any new or useful improvement thereof, copyrights, copyright registrations and applications for copyright registration, trademark, trade dress and service mark rights and registrations and applications for registration thereof, and all rights in trade secrets, computer software, data and databases, and mask works, all rights of attribution and integrity and other moral rights and all other intellectual property rights of any type, in each case whether registered or unregistered and including all applications for, and renewals and extensions of such rights and all similar or equivalent rights or forms of protection in any part of the world.

Intellectual Property Claim” means any claim, demand, suit or legal action arising out of or based on any actual or alleged unauthorized disclosure, use or misappropriation of any Intellectual Property, or, any actual or alleged infringement or other violation of any right in, to or under, any Intellectual Property of any other Person that: (a) concerns any materials, deliverables, Work Product or other services provided by Seller, any of its Affiliates, or any Subcontractor under the Agreement; (b) is based upon or arises out of the performance under the Agreement by Seller, any of its Affiliates, or any Subcontractor, including the use of any tools or other implements of construction by Seller, any of its Affiliates, or any Subcontractor; or (c) is based upon or arises out of Buyer’s exercise of its rights pursuant to and in accordance with Clause 18.

Key Personnel” means the project director appointed by Seller pursuant to Clause 3, each deputy project director and any other senior supervisory personnel as agreed between the Parties in writing.

kWh” means kilowatt hour.

Law” means all constitutions, treaties, laws, statutes, edicts, decrees, ordinances, rules, regulations, tariffs, codes, injunctions, writs, requirements, instructions, order and other legal acts of any Governmental Authority or any body under the control of a Governmental Authority.

Lender” means (i) any Person that does or proposes to lend money, finance or provide financial support or equity in any form in respect of the Facility and/or the general business and operations of Owner or each of its Affiliates (including any refinancing thereof), including any export credit agency, funding agency, bondholder, insurance agency, underwriter, investor, commercial lender or similar institution, together with any agent or trustee for such Person and (ii) any provider of any hedging arrangement entered into in connection with the arrangements described in clause (i) above, including an interest rate swap transaction or a forward interest rate swap transaction, in each case together with any agent or trustee for such provider.

Lender’s Engineer” is any Person appointed by the Lenders to represent them on technical matters related to the Facility.

 

A-6


Lien means any mortgage, deed of trust, pledge, lien, security interest, option agreement, conditional sale agreement, title retention agreement, claim, equity, attachment, covenant, condition or restriction, charge or encumbrance or any agreement of any kind, in or with respect to any real or personal property.

Liquefaction Train means the mixed refrigerant compression package, including the Cold Box, surge vessel and other equipment purchased by Buyer from Seller producing approximately [***] MTPA of LNG at design outlet pressure and ambient design conditions of [***] degrees Fahrenheit and [***] relative humidity, at sea level, as further described in Appendix C (Scope of Supply & Project Schedule).

Liquefaction Train Performance Guarantees means the Liquefaction Train Production Capacity Performance Guarantee and the Liquefaction Train Power Demand Performance Guarantee.

“Liquefaction Train Performance Tests” means the Liquefaction Train performance tests described in Appendix F (Performance Tests).

Liquefaction Train Power Demand Minimum Performance Guarantee means power demand for a Liquefaction Train of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train Production Capacity Performance Guarantee.

Liquefaction Train Power Demand Performance Guarantee means power demand for a Liquefaction Train of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train Production Capacity Performance Guarantee.

Liquefaction Train Power Demand Liquidated Damages has the meaning given to it in Clause 25.3(a).

Liquefaction Train Production Capacity Performance Guarantee means LNG production capacity of [***] MTPA.

Liquefaction Train Production Capacity Liquidated Damages has the meaning given to it in Clause 25.3(b).

Liquefaction Train System means the mixed refrigerant compression package, including the Cold Box, surge vessel and other equipment purchased by Buyer from Seller in a configuration of ten (10) Liquefaction Trains capable of producing an aggregate of approximately [***] MTPA of LNG at design conditions, as further described in Appendix C (Scope of Supply & Project Schedule).

Liquefaction Train System Performance Guarantees means the Liquefaction Train System Production Capacity Performance Guarantee, the Liquefaction Train System Power Demand Performance Guarantee, the Refrigerant Losses Performance Guarantee and the LNG Quality Performance Guarantee.

 

A-7


Liquefaction Train System Performance Delay Liquidated Damages Cap means an amount equal to [***] of the Aggregate Performance Delay Liquidated Damages Cap.

Liquefaction Train System Performance Tests means the Liquefaction Train System performance tests described in Appendix F (Performance Tests).

Liquefaction Train System Power Demand Minimum Performance Guarantee means power demand for the Liquefaction Train System of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train System Production Capacity Performance Guarantee.

“Liquefaction Train System Power Demand Performance Guarantee” means power demand for the Liquefaction Train System of [***] of LNG produced at design conditions and while satisfying the Liquefaction Train System Production Capacity Performance Guarantee.

Liquefaction Train System Power Demand Liquidated Damages has the meaning given to it in Clause 25.3(a).

Liquefaction Train System Production Capacity Performance Guarantee means LNG production capacity for the Liquefaction Train System of [***] MTPA and [***] at [***] and [***], without considering the maintenance cycle for the Liquefaction Trains.

Liquefaction Train System Production Capacity Liquidated Damages has the meaning given to it in Clause 25.3(b)(ii).

Liquidated Damages means Delivery Delay Liquidated Damages, Performance Delay Liquidated Damages and the Performance Liquidated Damages, collectively.

Liquidated Damages Cap means an amount equal to [***] of the Contract Price.

“LNG” has the meaning given to it in the Basis of Design.

LNG Quality Performance Guarantee means that the LNG composition meets the criteria in Annex C-2 of Appendix C (Scope of Supply & Project Schedule).

LNG Quality Liquidated Damages has the meaning given to it in Clause 25.3(b)(ii).

“LNTP” has the meaning given to it in Clause 6.6.

Losses means any and all losses, liabilities, damages, costs, charges, expenses, fines, interest, awards, penalties and taxes, which are the result of or arise in connection with any actions, suits, claims, demands, causes of action, litigation, lawsuits, administrative proceedings or administrative investigations.

Major Component has the meaning given to it in Clause 4.2.

 

A-8


Major Subcontractor” means any Subcontractor identified in Appendix G having a contract with Seller in relation to Seller’s performance of the Agreement with an aggregate value in excess of One Million Dollars ($1,000,000).

Maximum Termination Fee” has the meaning given to it in Clause 29.2.

Milestone” means an event that is identified as a milestone in the Project Schedule.

Minimum Performance Guarantees” means the Liquefaction Train Power Demand Minimum Performance Guarantee, the Liquefaction Train System Power Demand Minimum Performance Guarantee, and the Refrigerant Losses Performance Guarantee.

Mixed Refrigerant” means a mixture of gases or liquids, including ethylene, propane, i-pentane, nitrogen and other gases as may be required to operate a Liquefaction Train.

Module” means the natural gas liquefaction module forming part of a Liquefaction Train, as further described in Appendix C (Scope of Supply & Project Schedule).

Month” means a calendar month according to the Gregorian Calendar beginning at 12:00 midnight in the State of Louisiana, on the last Day of the preceding month and ending at 12:00 midnight in the State of Louisiana, on the last Day of the current month, unless otherwise specified herein as from another Day to the Day preceding the same Day of following Month.

Moody’s” means Moody’s Investor Services, Inc. and any successor thereto.

MTPA” means million Tonnes of LNG per annum.

Notice of Dispute” has the meaning given to it in Clause 20.1.

Operation And Maintenance Manuals” means the manuals described as such in Appendix C (Scope of Supply & Project Schedule).

Other Party” has the meaning given to in Clause 8.2.

Outside Intellectual Property” has the meaning given to it in Clause 18.6.

Owner” means Venture Global CP2 LNG, LLC and any of its successors and assigns.

Party” or “Parties” has the meaning given to it in the preamble of the Agreement.

Payment Milestone” means the event or group of events to be achieved in order to entitle Seller to invoice the payment, as listed in Appendix B (Pricing; Payment Terms & Cancellation Schedule).

Payment Schedule” has the meaning given to it in Clause 7.1.

 

A-9


Performance Delay Liquidated Damages means the Liquefaction Train Production Capacity Liquidated Damages, the Liquefaction Train System Production Capacity Liquidated Damages and the LNG Quality Liquidated Damages.

Performance Delay Liquidated Damages Cap means: (a) in respect of each Liquefaction Train, an amount equal to (i) [***] of the Aggregate Performance Delay Liquidated Damages Cap in respect of each of the first [***] Liquefaction Trains to be performance tested and (ii) [***] of the Performance Delay Liquidated Damages Cap in respect of each of the subsequent [***] Liquefaction Trains to be performance tested; and (b) in respect of the Liquefaction Train System Production Capacity Performance Guarantee and the LNG Quality Performance Guarantee, collectively, an amount equal to [***].

Performance Guarantees means the Liquefaction Train Performance Guarantees and the Liquefaction Train System Performance Guarantees.

Performance Liquidated Damages means the Liquefaction Train Power Demand Liquidated Damages and the Liquefaction Train System Power Demand Liquidated Damages.

Performance Liquidated Damages Cap means an amount equal to [***].

Performance Tests means the Liquefaction Train Performance Tests and the Liquefaction Train System Performance Tests.

Person means any individual, corporation, partnership, joint venture, limited liability company, association, joint stock company, trust, unincorporated organization, entity, government or other political subdivision.

PIS Purchase Order has the meaning given in the recitals of the Agreement.

Plaquemines Purchase Orders means that certain (a) Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January 19, 2022, between Seller and Venture Global Plaquemines LNG, LLC and (b) Purchase Order Contract for the Sale of Liquefaction Train System, dated as of August 5, 2022, between Seller and Venture Global Plaquemines LNG, LLC.

“Preservation Agreement” means the agreement that Buyer and Seller may negotiate and enter into pursuant to which (a) some or all of the Liquefaction Trains will be stored in a storage facility meeting Seller’s requirements for [***] or more, up to [***], and (b) Seller will for commercially reasonable market-based rates provide Buyer with preservation and maintenance services for such Liquefaction Trains while such Liquefaction Trains are in stored in the storage facility.

 

A-10


“Project Schedule” means the activity completion and delivery schedule set forth in Appendix C (Scope of Supply & Project Schedule).

“Qualified Financial Institution” means a U.S. commercial bank or a U.S. branch office of a foreign bank having, in either case, (a) assets of at least $10,000,000,000 and (b) a Credit Rating from one or both of S&P and Moody’s, which Credit Rating is at least “A-” from S&P (if such bank has a Credit Rating from S&P) and “A3” from Moody’s (if such bank has a Credit Rating from Moody’s).

“Ready for Test” means that the Liquefaction Train or the Liquefaction Train System, as applicable, (i) has been installed and is mechanically complete, (ii) has completed Seller’s commissioning and start-up activities pursuant to the Services Agreement, (iii) is capable of being operated safely in accordance with requirements under the EPC Agreement, and (iv) is ready for the Performance Tests to be performed in accordance with the Agreement.

“Rebatable Louisiana Sales and Use Tax” has the meaning given to it in Clause 8.2.

“Receiving Party” has the meaning given to it in Clause 22.1.

“Refrigerant Losses Performance Guarantee” means the loss in Mixed Refrigerant from compressor seals on one Liquefaction Train of [***] based on a normal back pressure of [***].

“Reliability Guarantee” has the meaning given to it in Clause 25.1(g).

“Representatives” means (a) in the case of Buyer, Buyer’s Representatives and (b) in the case of Seller, Seller’s Representatives.

“SDN” has the meaning given to it in Clause 16.5(a).

“S&P” means Standard & Poor’s Corporation and any successor thereto.

“Seller” means Baker Hughes Energy Services LLC, together with its successors and permitted assigns, who shall sell and deliver the Liquefaction Trains under the Agreement.

“Seller Competitors” means [***] or any of their respective Affiliates and any other entities that are competitors of Seller [***], as Buyer and Seller may agree from time to time.

“Seller Developed Intellectual Property” has the meaning given to it in Clause 18.3.

“Seller Excluded Parties” means Seller and its Affiliates and all of their respective directors, officers, assigns and employees and Seller’s Approved Subcontractors, and General Electric Company and each of its subsidiaries, owners, shareholders and all of their respective directors, officers, assigns and employees.

 

A-11


Seller Parent Company Guarantee” means the guarantee, in the form set out in Appendix H (Form of Seller Parent Company Guarantee), to be issued by Seller’s Guarantor and delivered by Seller to Buyer in accordance with Clause 7.9.

Seller’s Guarantor” means Baker Hughes Holdings LLC, a Delaware limited liability company.

Seller’s Know-How” means all of the information, technique and/or know-how related to the design, engineering, manufacturing, construction, operation, maintenance, optimization, repair and servicing of the Liquefaction Train System which was owned by Seller prior to the Agreement or acquired by Seller during performance of the Agreement.

Seller Parties” means Seller and its Affiliates and all of their respective directors, officers, agents, advisors, engineers, contractors, consultants, representatives, assigns, employees and any other Person acting on behalf of any of them or in representation, interest, benefit thereto.

Seller’s Representatives” has the meaning given to it in Clause 22.1.

Seller Taxes” means any and all existing or future (a) corporate and personal income taxes imposed on Seller and its employees by the applicable Laws of any country and (b) taxes, Duties, fees, or other charges of any nature (including, but not limited to, ad valorem, consumption, excise, franchise, gross receipts, import, export, license, property, sales and use, stamp, storage, transfer, turnover, or value-added taxes, or other similar taxes, and any and all items of deficiency, penalty, addition to tax, interest, or assessment related thereto), imposed by any Governmental Authority of any country, other than the United States of America (or any political subdivision thereof), in connection with the execution of the Agreement, Seller’s sale and delivery of the Liquefaction Trains or Seller’s performance of its other obligations under the Agreement.

Serial Defect” has the meaning given to it in Clause 17.2(c).

Services” means all the services to be provided under the attendant and separate Services Agreement.

Services Agreement” means the field services agreement between Buyer, or Owner, and the Services Provider to be entered into on or before Financial Closing under which the Services Provider will for commercially reasonable market based rates provide Buyer, or Owner, with technical field services, training, the on-Site supervision of the installation, start-up, commissioning and testing of the Liquefaction Trains and the oversight of the operation and maintenance of the Liquefaction Trains that commence commercial operations prior to the Substantial Completion of the Facility.

Services Provider” means Seller or Seller’s Affiliate that provides the Services under the Services Agreement.

 

A-12


Site” means the site located in Cameron Parish, Louisiana, south of Lake Charles, Louisiana, adjacent to the site set forth under the Calcasieu Purchase Order, as further described in Appendix C (Scope of Supply & Project Schedule).

Spare Parts” has the meaning given to it in Clause 13.3.

Subcontractor” means any Person to whom any part of Seller’s obligations under the Agreement has been subcontracted to by Seller.

Substantial Completion of the Facility” means “Facility Substantial Completion” as defined in the EPC Agreement.

Substantial Completion of the Liquefaction Train” means that the Liquefaction Train (i) has achieved Ready for Test, (ii) has completed the Liquefaction Train Performance Tests and (iii) either (1) has satisfied all Liquefaction Train Performance Guarantees or (2) has satisfied the Liquefaction Train Power Demand Minimum Performance Guarantee and Seller has paid all payable liquidated damages for the Liquefaction Train Performance Guarantees that were not met.

Substantial Completion of the Liquefaction Train System” means that the Liquefaction Train System (i) has achieved Ready for Test, (ii) has completed the Liquefaction Train System Performance Tests and (iii) either (1) has satisfied all Liquefaction Train System Performance Guarantees or (2) has satisfied the Liquefaction Train System Power Demand Minimum Performance Guarantee and the Refrigerant Losses Performance Guarantee and Seller has paid all applicable liquidated damages for the Liquefaction Train System Performance Guarantees that were not met.

Technical Documentation” means all technical documentation, specifications, samples, patterns, models, calculations, computer programs (software), Operation And Maintenance Manuals and other documents or information of a similar nature, to be submitted by Seller to Buyer in native files, in accordance with Clause 18, and .PDF in accordance with Appendix C (Scope of Supply & Project Schedule). A list of files required to be submitted in native format is set forth in Appendix C (Scope of Supply & Project Schedule).

Termination Fee” has the meaning given to it in Clause 29.2.

Tonne” means metric ton and is defined as 2204.6 lbs.

Transportation Costs” has the meaning given to it in Clause 7.1.

Transshipment Facility” has the meaning given to it in Clause 9.1.

Unconditional Performance Obligation” means Seller’s absolute obligation to achieve (a) the Liquefaction Train Production Capacity Performance Guarantee for each and every Liquefaction Train; (b) the Liquefaction Train System Production Capacity Performance Guarantee; (c) the LNG Quality Performance Guarantee; (d) the Minimum Performance Guarantees; and (e) the Reliability Guarantee.

 

A-13


Warranty Period” means the period, specified as such in Clause 17.1.

Week” means a calendar week consisting of seven (7) Days.

Working Day” means any Day other than a Saturday, or a Sunday or a legal holiday in the State of New York (solely for the purpose of a payment obligation) or the State of Louisiana (with respect to all other obligations).

Work Product” has the meaning given to it in Clause 18.1.

 

1.2

Interpretation

In the Agreement, unless the context otherwise requires or the relevant provision(s) expressly state otherwise:

 

  (a)

the headings to the clauses and the emphasizing are for convenience only and do not affect the interpretation of the Agreement;

 

  (b)

all references to documents or other instruments include all amendments and replacements thereof and supplements thereto;

 

  (c)

all references to any statute or statutory provision shall include references to any statute or statutory provision which amends, extends, consolidates or replaces the same or which has been amended, extended, consolidated or replaced by the same and shall include any orders, regulations, instruments or other subordinate legislation made under the relevant statute;

 

  (d)

reference to a ‘Person’ or ‘Persons’ or a ‘party’ or ‘parties’ includes individuals, bodies corporate, unincorporated associations and partnership and that Person’s or those Persons’ personal representatives, successors and permitted assignees, private or public bodies or individuals;

 

  (e)

any obligation on a Party to do anything shall be deemed to include an obligation to procure such thing to be done; any obligation not to do anything shall be deemed to include an obligation not to permit or not to suffer such thing;

 

  (f)

when a time-limit is determined in Days, it expires at the end of the last Day and it is counted from Day to Day; when it is determined in Months, it is counted from Day of Month to Day of Month; if the last Day of either time-limit is a public holiday, the time-limit is extended to the end of the first Working Day that follows;

 

  (g)

save exceptions agreed to by Buyer, the only measurement units admitted are the internationally used measurement units of the metric system;

 

A-14


  (h)

if any reference is made in the Agreement to Incoterms or any standards such as ISO standards, the particular Incoterms or standards will apply only:

 

  (i)

to the particular item in respect of which they are used; and,

 

  (ii)

to the extent that such application is not conflicting with the content of the Agreement;

 

  (i)

‘including’ shall, unless expressly stated otherwise, mean ‘including without limitation’;

 

  (j)

references to a ‘Clause’ shall be to a clause of the Agreement;

 

  (k)

the singular number includes the plural number and vice versa;

 

  (l)

reference to any gender includes the other;

 

  (m)

‘hereunder,’ ‘hereof,’ ‘hereto’ and words of similar import shall be deemed references to the Agreement as a whole and not to any particular Clause or other provision hereof or thereof;

 

  (n)

the term ‘or’ is not exclusive, regardless of whether ‘and/or’ is used in the applicable provision; and

 

  (o)

if the Buyer assigns the Agreement to the EPC Contractor, all references to “Buyer” hereunder shall be treated as a reference to “EPC Contractor”, and if Buyer does not assign the Agreement to the EPC Contractor, each reference to “Buyer” hereunder shall be treated as a reference to “Owner”.

 

1.3

Communications - Notices

Any notice, instruction, consent, approval, comment, certificate or determination to be given in connection with the Agreement shall be effective only if in writing and addressed to the Person, as each Party or Owner has identified below: (a) on delivery, if delivered personally to the Person; (b) on transmission, if transmitted to the facsimile number of the Person or by electronic mail; and (c) on posting, if by first class or overnight mail (postage prepaid). No change of address for a Party or Owner shall be effective until written notice of the change of address is provided to the other Parties and Owner in accordance with this Clause 1.3.

 

A-15


If to Buyer:    [***]
with a copy to:    [***]
If to Seller:    [***]
and:    [***]
with a copy to:    [***]
If to Owner:    [***]
with a copy to:    [***]

 

1.4

Language

 

  (a)

All correspondence between Buyer and Seller as well as all Technical Documentation and comments thereto and shipping marks shall be in English.

 

A-16


  (b)

The Operation and Maintenance Manuals, all markings on equipment, labels, signboards, instrument dials, graphical interfaces with the process control system, safety documentation, machine and component name plates shall be in English.

 

1.5

No Joint Venture, Partnership or Association

 

  (a)

The Agreement shall not be interpreted or construed to create an association, joint venture, or partnership between the Parties or to impose any partnership obligation or liability upon either Party.

 

  (b)

Neither Party shall have any right, power or authority to enter into any agreement or undertaking for, or act on behalf of, or to act as or be an agent or representative of, or to otherwise bind, the other Party.

 

1.6

Parties to act reasonably

 

  (a)

Where reference is made in the Agreement to a Party’s decision, approval, refusal, consent, agreement, act, etc., such shall not be taken, given or withheld unreasonably or unfairly, unless otherwise expressly stated.

 

  (b)

In all cases the Party claiming a breach of the Agreement by the other Party, shall be obligated to make commercially reasonable efforts to mitigate its costs, losses or damages that have occurred or that may occur as a result of such breach.

 

2.

REQUESTS AND CLARIFICATIONS

Seller represents and warrants to Buyer that Appendix C (Scope of Supply & Project Schedule) includes all of the necessary obligations that are required to be performed by Seller in order for the Liquefaction Train System to operate in accordance with the requirements of the Agreement and satisfy the design codes, standards and the Performance Guarantees set forth in the Agreement. The Parties acknowledge and agree that Appendix C (Scope of Supply & Project Schedule) describes the items for the Liquefaction Train System being provided in general, but not in complete detail. The Parties agree that any specific items not set forth in Appendix C (Scope of Supply & Project Schedule), or any details or clarifications thereto, that are required in order to satisfy the requirements of the Agreement or to satisfy the design codes, standards and the Performance Guarantees set forth in the Agreement, in each case, will not be considered changes to Appendix C (Scope of Supply & Project Schedule), unless they are explicitly excluded from Appendix C (Scope of Supply & Project Schedule), or are changes to the Basis of Design directed by Buyer, or are changes associated with a Change Order issued pursuant to Clause 24, and Seller waives any right to increase the Contract Price or the Project Schedule with respect thereto. The Parties acknowledge and agree that Appendix C (Scope of Supply & Project Schedule) contains certain single-line diagrams, pipe and instrumentation diagrams and other diagrams and drawings that may change as Seller completes its engineering of the Liquefaction Train System and that any change to such diagrams and drawings, which are not the result of changes to the Basis of Design directed by Buyer, or changes pursuant to the Change Order requirements of Clause 24, will not be changes that will entitle either Party to changes in the Contract Price or an extension of the Project Schedule.

 

A-17


Buyer may issue to Seller requests or non-material clarifications that are not inconsistent with the obligations of Seller under Appendix C (Scope of Supply & Project Schedule) which Buyer may consider necessary or helpful to Seller in the performance of Seller’s obligations under the Agreement. Seller will evaluate Buyer’s requests or clarifications within a reasonable time period and provide feedback in writing to Buyer. Seller agrees to cooperate with Buyer’s other contractors, including the EPC Contractor.

In the event any such request or clarification of Buyer is transmitted orally, Seller may require Buyer to confirm such request or clarification in writing. Seller shall notify Buyer of such requirement to confirm in writing without undue delay but in any event within seven (7) Working Days of receipt of Buyer’s verbal transmission. If Seller has requested such written confirmation, the request or clarification shall not be effective until written confirmation thereof has been received by Seller.

Any such request or clarification from Buyer shall not relieve Seller from its responsibility for delivering the Liquefaction Trains and performing its other obligations in accordance with the Agreement.

Seller and Buyer agree to reasonably cooperate and work together in good faith with the shared objective of using the experience, knowledge and data derived from the performance under the Agreement, the Initial LTS Purchase Order, the Calcasieu Purchase Order and the Plaquemines Purchase Orders to optimize the project management services, engineering services, procurement, manufacturing and performance of the Liquefaction Train System in combination with the balance of plant of the Facility (excluding Seller’s improvements that are unrelated to and do not impact the performance, reliability or maintenance of the Liquefaction Train System) with the common goals of (a) increasing the operational performance of the Liquefaction Train System and (b) if possible and solely to the extent consistent with clause (a), reducing the Contract Price; provided, however, that Seller and Buyer acknowledge that (i) no particular result is assured or guaranteed from such price optimization efforts and (ii) Seller shall not be permitted to change the means and methods of its performance or the Basis of Design: (1) in a manner that would deny or reduce the value to Buyer of the benefits of the optimization of the performance of the Liquefaction Train System achieved by Buyer or (2) except as contemplated under Clause 6.6, without the prior written approval of Buyer. Prior to implementation, Buyer shall consult with Seller in respect of any modifications that adversely and materially impact the inlet, exit or throughput conditions of the Liquefaction Train System. Notwithstanding the foregoing, if and to the extent that Seller makes adjustments to its means and methods or design specifications under the Initial L TS Purchase Order after the Effective Date that relate to Seller achieving the performance guarantees set forth in the Initial LTS Purchase Order, such adjustments may be incorporated into the Agreement.

 

A-18


3.

PROJECT DIRECTOR AND DOCUMENT MANAGEMENT SYSTEM

 

A.

Seller shall provide all oversight and superintendence that is necessary for the performance of its obligations, and obligations of its personnel and the personnel of its Subcontractors, under the Agreement. Seller shall appoint by no later than the Effective Date a competent and authorized representative who shall act as project director and devote the necessary time to the oversight and superintendence of the same and who shall have the authority to act on Seller’s behalf under the Agreement and receive, on behalf of Seller, requests or clarifications from Buyer. In addition, to the extent that such persons are still employees of Baker Hughes Company, then Seller shall make available to Buyer for the performance of this Agreement the same senior supervisory personnel that are presently engaged with Buyer in respect of the liquefaction trains under the Initial L TS Purchase Order. The replacement of, or additions to, the Key Personnel shall only be made with persons having qualifications and experience comparable to those being replaced or added to. In connection with any substitution of Key Personnel, Buyer shall (a) include a detailed explanation and reason for the request and the resumes of professional education and experience for a minimum of two (2) candidate(s) of suitable qualifications and experience and (b) discuss such candidates in advance with Buyer in order to allow Buyer to provide feedback and request for clarifications. Seller shall use commercially reasonable efforts to take Buyer’s recommendations into consideration. In addition, Buyer may if it is concerned with the performance of any Key Personnel request the removal of, and Seller shall use commercially reasonable efforts to comply with such request to remove and replace, such Key Personnel; provided that if Buyer reasonably demonstrates that such Key Personnel has: (i) been gravely incompetent or negligent in the performance of his or her duties, or (ii) engaged in activities in material violation of the Law or of any safety and security protocols of Buyer that were communicated to Seller in writing, Seller shall promptly remove such Key Personnel and replace such Key Personnel in accordance with this Clause 3.

 

B.

The Parties agree that they will use the document management system designated by Buyer from time to time as the primary medium of communication for all engineering drawings and project management monthly reports. If the Agreement requires information to be delivered within a specified time, such delivery shall be deemed to have occurred at the date and time such information is uploaded on Buyer’s document management system in electronic form and Buyer is electronically notified of such upload activity within one (1) hour of such upload activity.

 

4.

ASSIGNMENT AND SUBCONTRACTING

 

4.1

Assignment

Buyer shall not transfer or assign the Agreement or any of its rights under or interest in the Agreement (including monies that are due or monies that may be due) without the prior written consent of Seller, which consent shall not be unreasonably withheld, conditioned or delayed; provided, however, that Buyer shall not need the consent of Seller (a) to transfer

 

A-19


or assign the Agreement to its Affiliate (to the extent such Affiliate is organized under the laws of the United States of America), (b) to transfer or assign the Agreement to the EPC Contractor subject to the requirements under this Clause 4.1 or (c) to assign, charge or otherwise encumber the Agreement or any rights or benefits arising thereunder or therefrom by way of collateral in favor of Lenders. Seller may only transfer or assign the Agreement or any of its rights under or interest in the Agreement (including monies that are due or monies that may be due) with the prior written consent of Buyer, which consent shall not be unreasonably withheld, conditioned or delayed; provided, however, that Seller shall not need the consent of Buyer to assign or novate the Agreement to any Affiliate of Seller that is ultimately wholly owned by Baker Hughes Company and assign any receivables due Seller hereunder to one (1) or more Affiliates of Seller or to third parties. The Parties agree to execute such documents as may be necessary to effect any permitted assignments or transfers of the Agreement. In connection with any collateral assignment of the Agreement by Buyer, Seller shall provide any customary agreements, certificates, legal opinions or other documents reasonably required by any Lender. In connection with any assignment of the Agreement to the EPC Contractor by Buyer, Seller shall agree to any modifications to the Agreement that are reasonably requested by the EPC Contractor, so long as such modifications do not impose any additional risk, costs, expenses or liability on Seller or Owner. In the event of a transfer or assignment of the Agreement by (i) Buyer, (A) Buyer’s assignee or transferee shall have financial capabilities, directly or by virtue of credit enhancements or other financial arrangements, that are comparable or better than Buyer’s, as of the Effective Date, and (B) Buyer shall cause the credit support under Clause 7.8 to be maintained or provide Seller with replacement credit support that is reasonably acceptable to Seller and substantially similar as provided to Seller hereunder (in which case, if the conditions of Clause 4.1 (i)(A) and (i)(B) are met, any credit support that was provided to Seller prior to such assignment shall be promptly returned by Seller to Buyer) and (ii) Seller, Seller shall cause the credit support under Clause 7.9 to be maintained or provide Buyer with replacement credit support that is reasonably acceptable to Buyer and substantially similar as provided to Buyer hereunder. Any assignment, novation, transfer or other disposal in violation of this Clause 4.1 shall be null and void ab initio and shall not be binding on the Parties. For any assignment by Buyer of the Agreement either to Affiliates, EPC Contractor or any other third parties, Buyer acknowledges that Seller shall perform its standard “Know Your Customer” due diligence (which involves various compliance and financial due diligence) on the proposed assignee and the proposed assignee must satisfy the “Know Your Customer” requirements.

 

4.2

Subcontracting

Seller and Buyer agree that Seller may not utilize the services of any Subcontractors without obtaining Buyer’s prior written approval, which approval may not be unreasonably delayed or withheld. As of the Effective Date, Buyer has agreed that Seller may, subject to the remaining provisions of this Clause 4.2 and Clause 8.4, utilize the services of the Approved Subcontractors listed in Appendix G (Approved Subcontractors). Seller may only utilize the services of the Approved Subcontractors (a) that satisfy Buyer’s quality requirements and (b) in accordance with the requirements set forth in this Clause 4.2. If Seller is considering utilizing the services of any Subcontractor that is not an Approved

 

A-20


Subcontractor, then Seller shall notify Buyer of its proposal for such Subcontractor to become an Approved Subcontractor and furnish to Buyer all information reasonably requested by Buyer with respect to the qualifications of such proposed Subcontractor. Buyer shall have the right, acting reasonably, to reject any such proposed Subcontractor, and Seller shall not enter into any subcontract with such proposed Subcontractor that is rejected by Buyer. If an Approved Subcontractor, that has been selected to provide or is providing equipment, becomes subject to bankruptcy or insolvency proceedings or is unable, in Seller’s reasonable judgment, to supply all of the relevant equipment due to capacity constraints, Seller and Buyer will collaborate to develop a list of three or fewer acceptable Subcontractors to replace or supplement such Approved Subcontractor, and shall amend Appendix G accordingly. If Buyer rejects such proposed Subcontractor and the existing Approved Subcontractors are not acceptable in Seller’s reasonable determination for price, quality or schedule reasons, then Seller shall be entitled to a Change Order for any resulting incremental increase in price or delay in the Delivery Date as a result of Buyer’s rejection of such proposed Subcontractor. Approval of any Subcontractor under this Clause 4.2 shall only be for the portion of Seller’s obligations so approved by Buyer. No subcontract with an Approved Subcontractor shall bind or purport to bind Buyer, but each such subcontract shall contain a provision permitting its assignment to Buyer, Owner or the Lenders upon Buyer’s or Seller’s written request.

Seller acknowledges and agrees that Buyer shall have the right to consent to and approve the supplier of each major component of equipment comprising the Liquefaction Train System, [***] (each a “Major Component”), and confirms the strategy to use the same Approved Subcontractor identified on Appendix G for each item, as identified by its specific Tag Number, for all Liquefaction Trains. To assist Buyer in the selection of Major Components, for each potential vendor or supplier of a Major Component, Seller agrees to provide Buyer with access to: (a) the identity of the potential vendor or supplier; (b) the delivery and schedule terms for the Major Component; and (c) all technical and performance information for each Major Component requested by Buyer. To the extent a Major Component supplier is changed based on a Buyer directive and, as a result of such change in Major Component supplier, Seller incurs a documented incremental increase in the price of the Major Component or delay in the delivery of the Major Component that adversely affects the Delivery Date, Seller shall be entitled to a Change Order for an equitable adjustment in the Contract Price and the Project Schedule for the applicable Liquefaction Train System.

Seller further acknowledges that it shall notify Buyer before subcontracting with any Major Subcontractor (excluding for the avoidance of doubt any Approved Subcontractor) supplying materials or fabrication services in connection with the performance of the Agreement that is located in Asia. Buyer shall have the right to reject any such Major Subcontractor so long as a reasonably comparable subcontractor located outside of Asia is identified as capable of performing the relevant scope of supply, and in such event Seller shall not enter into a subcontract with the Asia-based entity. If Buyer has rejected such

 

A-21


proposed Major Subcontractor and the comparable subcontractor located outside of Asia that was identified as capable of performing the relevant scope of supply is not acceptable, in Seller’s reasonable determination, for price, quality or schedule reasons (with Seller having validated for Buyer its determination as to such comparable subcontractor), then, unless such comparable subcontractor is an Approved Subcontractor, Seller shall be entitled to a Change Order for any resulting incremental and documented increase in the Contract Price or adjustment to the Project Schedule, in each case as a result of Buyer’s rejection of such proposed Major Subcontractor.

 

4.3

Other

 

  (a)

Seller hereby acknowledges and agrees that the review or acceptance of any contract between Seller and an Approved Subcontractor by Buyer and the acceptance of the Approved Subcontractors shall not: (i) modify or relieve, in any way, the obligations of Seller pursuant to the Agreement; (ii) be raised as a claim or as a defense or counterclaim to any claim in connection with the Agreement; or (iii) constitute any approval or acceptance of the work, services or equipment provided under such subcontract or by such Approved Subcontractor.

 

  (b)

At a minimum, all contracts between Seller and an Approved Subcontractor shall require the following:

 

  (i)

such Approved Subcontractor shall comply with all applicable professional standards, permits and Laws, rules, codes and regulations and with the performance standards of Seller under the Agreement;

 

  (ii)

Buyer and Owner shall have all the inspection rights that Buyer and Owner have under the Agreement;

 

  (iii)

such Approved Subcontractor shall be subject to the applicable labor obligations and the safety and security provisions under the Agreement;

 

  (iv)

such Approved Subcontractor shall provide guarantees and warranties with respect to the work and services performed and the materials provided under such contract;

 

  (v)

such Approved Subcontractor shall (A) obtain and carry the insurance coverages (with limits appropriate to the value of such contract) required of Seller pursuant to Clause 23 from an insurance carrier with an A rating from A.M. Best and naming Buyer as an “additional insured”, and (B) provide certificates of insurance as set forth herein;

 

  (vi)

such contract shall be subject to the dispute resolution procedures as set forth herein;

 

A-22


  (vii)

such Major Subcontractor(s) shall provide the applicable Lien waiver and releases required under Clause 7.6, in connection with each payment to Seller hereunder;

 

  (viii)

such Approved Subcontractor(s) shall grant a license to Buyer in accordance with Clause 18.1 and Clause 18.3;

 

  (ix)

such contract shall be subject to the confidentiality provisions set forth under the Agreement; and

 

  (x)

such contract shall be subject to the anti-corruption provisions set forth in Clause 16.5.

 

  (c)

All contracts between Seller and an Approved Subcontractor must specify that the contractual relationship with such Approved Subcontractor is exclusive to Seller and that such Approved Subcontractor waives any and all rights to demand any payment directly from Buyer and Owner. All contracts between Seller and Approved Subcontractors shall preserve and protect the rights of Buyer and Owner, shall not prejudice such rights and shall require each Approved Subcontractor to enter into similar agreements with its subcontractors. As between Seller and Buyer, Seller shall be solely responsible for the acts, omissions or defaults of the Approved Subcontractors and their agents, representatives and employees. Nothing in the Agreement shall be construed to impose on Buyer or Owner any obligation, liability or duty to an Approved Subcontractor or any other Subcontractor or to create any contractual relationship between any Subcontractor, including any Approved Subcontractor, or other third party and Buyer, including an obligation to pay or to see to the payment of any moneys due any such Subcontractor, Approved Subcontractor or other third party.

 

  (d)

No Approved Subcontractor is intended to be nor shall be deemed a third party beneficiary of the Agreement. In addition to the requirements set forth above, Seller shall include in each contract with an Approved Subcontractor language under which Buyer and Owner shall be made express third party beneficiaries of such contract. If any Approved Subcontractor or proposed Subcontractor refuses to name Buyer and Owner as a third party beneficiary or provide for a right of assignment to Buyer, then Seller shall not use such Subcontractor for any portion of Seller’s obligations hereunder, unless Buyer’s prior written consent is obtained.

 

  (e)

Contingent upon receipt of Buyer’s designation in writing as set forth below, Seller hereby assigns to Buyer (and Buyer’s permitted assigns) all its interest in any contracts with Approved Subcontractors (or any portion thereof to the extent such contracts also relate to other projects of Seller) now existing or hereafter entered into by Seller for performance of any part of the work or services, or provision of any materials under the Agreement. Such assignment of Approved Subcontractor contracts will be effective upon written acceptance by Buyer in writing and only as to those contracts which Buyer designates in such written acceptance.

 

A-23


5.

SCOPE

Seller agrees to have the Liquefaction Modules manufactured at Seller’s Affiliate’s manufacturing facilities located in [***] and to sell and deliver the Liquefaction Trains and provide the associated Technical Documentation to Buyer as set forth in Appendix C (Scope of Supply & Project Schedule) by the respective Delivery Dates, all in compliance with all other obligations under the Agreement.

 

6.

COMPLIANCE WITH TIME-LIMITS

 

6.1

Time for delivery

Seller shall diligently proceed with the performance of its obligations under the Agreement in accordance with the Project Schedule and the other requirements of the Agreement.

 

6.2

Progress of Works - Delay

Seller shall cause each Liquefaction Train to be delivered on or before the Delivery Date for such Liquefaction Train. If, at any time, Seller’s actual progress with respect to a Liquefaction Train is not consistent with meeting the Delivery Date for such Liquefaction Train, or as from the moment any of Seller’s personnel working on the Liquefaction Train System becomes aware of the fact that a Milestone for a Liquefaction Train cannot be met that will affect the Delivery Date for a Liquefaction Train, Seller shall promptly provide written notice to Buyer of such occurrence and shall develop, a recovery plan to overcome the anticipated delay and provide to Buyer, within ten (10) Working Days of such occurrence, a report identifying:

 

  (a)

the likely period of delay;

 

  (b)

the event causing the delay;

 

  (c)

the impact which such event has had or in the opinion of Seller is likely to have or will have on its ability to achieve any of the Milestones;

 

  (d)

the recovery plan developed by Seller to overcome the anticipated delay and the steps which Seller has taken, is taking and will take to mitigate the adverse consequences of such event; and

 

  (e)

further particulars of the consequences of the delay as Seller becomes aware.

Seller shall, in consultation with Buyer, implement the recovery plan and use best efforts to minimize or remove the actual or anticipated delay and any consequences thereof. If Buyer provides notice to Seller that Buyer reasonably believes that the steps proposed by Seller fail to adequately address the anticipated delay in meeting the Milestones as part of the recovery plan developed by Seller, then Seller shall increase its efforts in order to remove or minimize such anticipated delay.

 

A-24


6.3

Restriction on Change Order for Extension of Delivery Date

Seller shall not be entitled to a Change Order for an extension of time under the Agreement and/or reimbursement of Costs to the extent that such extension or reimbursement is due to any act, omission or default on the part of Seller or any Subcontractor.

 

6.4

Delivery Delay Liquidated Damages

 

  (a)

Each Liquefaction Train and certain Deliverables have a Delivery Date. If Seller fails to deliver a Liquefaction Train or such Deliverable by its associated Delivery Date, as the Delivery Date may be extended according to a Change Order, Seller shall be obligated to pay to Buyer liquidated damages (the “Delivery Delay Liquidated Damages”) for delay in achieving the Delivery Date as from the first Day following the scheduled Delivery Date until the Day on which delivery of (i) that specific Liquefaction Train to the Delivery Point actually occurs, provided that Seller shall not be obligated to pay Delivery Delay Liquidated Damages for any Day (or part thereof) beyond [***] that is required for a Liquefaction Train to clear customs in the Country for reasons that are not attributable to Seller’s or its Subcontractors’ acts or omissions or (ii) that specific Deliverable to Buyer actually occurs.

 

  (b)

The Delivery Delay Liquidated Damages payable by Seller to Buyer for each Day of delay in delivery of a specific Deliverable to Buyer beyond the Delivery Date for such Deliverable is [***] per Day. The aggregate amount of the Delivery Delay Liquidated Damages payable by Seller to Buyer for all Deliverables shall not exceed [***].

 

  (c)

For each Liquefaction Train the liquidated damages payable by Seller to Buyer for each Day of delay in delivery of the specific Liquefaction Train (in its entirety) to the Delivery Point beyond the Delivery Date is (i) in respect of the first [***] Liquefaction Trains to be delivered, an amount equal to: (1) for each of the first [***] Days of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days; (ii) in respect of the subsequent [***] Liquefaction Trains an amount equal to: (1) for each of the first [***] Days of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each day of such delay for the next [***] days.

 

A-25


  (d)

The aggregate amount of Delivery Delay Liquidated Damages payable by Seller to Buyer for (i) each Liquefaction Train shall not exceed the applicable Delivery Delay Liquidated Damages Cap, and (ii) all Liquefaction Trains shall not exceed the Aggregate Delivery Delay Liquidated Damages Cap. Liquidated Damages payable by Seller to Buyer shall not exceed the Liquidated Damages Cap. Once Seller has accrued Delivery Delay Liquidated Damages in an amount equal to the Delivery Delay Liquidated Damages Cap or Aggregate Delivery Delay Liquidated Damages Cap, as applicable, Buyer shall be entitled to exercise the rights provided in Clause 6.5.

 

  (e)

Buyer shall invoice Seller for any amounts due for Delivery Delay Liquidated Damages. Payment of any Delivery Delay Liquidated Damages shall occur by Seller within [***] following the date Buyer submits to Seller an invoice therefore. Buyer and Seller agree that the amount of Delivery Delay Liquidated Damages are reasonable in light of the anticipated harm caused by the breach of duty related thereto and the difficulties of proof of loss and inconvenience or non-feasibility of obtaining any adequate remedy with respect to the actual level of damages Buyer is likely to suffer as the result of a Delivery Delay Event, and the Parties are estopped from contesting the validity or enforceability of such liquidated damages. Except as provided in Clause 28.1 and Clause 28.3, the payment of Delivery Delay Liquidated Damages during the period prior to the Delay Limit Date shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for any Delivery Delay Event. In the event the Delivery Delay Liquidated Damages provisions in the Agreement are found for any reason to be void, invalid or otherwise inoperative so as to disentitle Buyer from claiming and recovering Delivery Delay Liquidated Damages from Seller for any Delivery Delay Event, Buyer shall, in addition to the remedies set forth below in Clause 6.5, be entitled to claim against Seller and recover for damages for any Delivery Delay Event; provided that such damages shall not exceed the limitations set forth in Clause 6.4(d).

 

6.5

Delays - Other remedies

Notwithstanding Clause 6.2, if Seller has reached the Delay Limit Date, Buyer may by notice to Seller, at Buyer’s sole discretion:

 

  (a)

require Seller to agree, within [***] of Buyer’s demand, to remedy the Delivery Delay Event, within the period of time identified by Buyer, at Buyer’s sole discretion. If Seller fails to agree within [***] of Buyer’s demand, or fails to remedy the Delivery Delay Event within such agreed period(s), Buyer shall be free to exercise its rights or remedies under clause (b) hereafter; or

 

  (b)

terminate the Agreement in accordance with Clause 28.l(g) and seek to recover from Seller Buyer’s damages pursuant to Clause 28.3 (subject to the limit of liability cap in Clause 19.2) arising from the applicable Delivery Delay Event, and, upon such termination by Buyer, Seller shall deliver to Buyer the portions of the Liquefaction Train System for which Seller has received payment and which have not been delivered to the Delivery Point; provided, however, that Buyer shall not be entitled to terminate the Agreement for so long as Seller continues to pay Buyer the applicable Delivery Delay Liquidated Damages, despite the fact that the aggregate amount of Delivery Delay Liquidated Damages paid by Seller have exceeded the limitations set forth in Clause 6.4(d).

 

A-26


6.6

Issuance of LNTP and FNTP

 

  (a)

The Project Schedule assumes that a limited notice to proceed (“LNTP”) authorizing the LNTP scope described in Appendix B (Pricing, Payment Terms & Cancellation Schedule) and Appendix C (Scope of Supply & Project Schedule) will be issued by Buyer no later than [***] Days prior to the issuance of the full notice to proceed authorizing Seller to proceed with the full scope of work under the Agreement (“FNTP”). If the LNTP is issued less than [***] Days prior to the issuance of the FNTP, the Project Schedule shall be extended day for day for each day that the LNTP was issued less than [***] Days prior to the issuance of the FNTP. In the event that no LNTP is issued prior to issuance of the FNTP, the Project Schedule shall be extended by [***] Days.

 

  (b)

Seller and Buyer acknowledge and agree that the amount payable under the LNTP shall be [***]. In case that LNTP is issued and if Buyer fails to issue the FNTP within [***] Days, Seller and Buyer shall jointly consider actions that can be taken to preserve subcontracts with Major Subcontractors and facilitate the procurement of critical long-lead time equipment and materials (including Major Components).

 

  (c)

If Buyer fails to issue the FNTP within [***] Days following the Effective Date, Seller shall be entitled to a Change Order for an equitable adjustment of the Contract Price and, if the Project Schedule is adversely affected, an equitable adjustment to the Project Schedule. If Buyer fails to issue the FNTP within [***] Days following the Effective Date, the senior management of Buyer and Seller shall meet within [***] Days thereafter to discuss when, if at all, the FNTP will be issued. If, after the senior management meeting there is no mutual agreement on extending the time for issuance of the FNTP, either Buyer or Seller may terminate the Agreement in which case Buyer shall pay Seller the applicable Termination Fee.

 

  (d)

Buyer may issue additional LNTPs for scope beyond what is provided in Appendix C (Scope of Supply & Project Schedule) pursuant to a Change Order issued pursuant to Clause 24.1.

 

6.7

Delivery Bonus

 

  (a)

If Seller delivers [***] Liquefaction Trains to Buyer at the Delivery Point before the applicable Delivery Date for each Liquefaction Train set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule), then the bonus amount payable to Seller shall be [***].

 

A-27


  (b)

In addition to the bonus amount in Clause 6.7 (a):

(i) If Seller delivers all [***] Liquefaction Trains to Buyer at the Delivery Point before the applicable bonus dates set forth in Annex C-1 of Appendix C (the “Bonus Dates”) for each Liquefaction Train, an additional bonus amount of [***] shall be payable to Seller; or

(ii)If Seller delivers one or more Liquefaction Trains to Buyer at the Delivery Point before the applicable Delivery Date for such Liquefaction Train(s), but after the applicable Bonus Date, the amount payable to Seller with respect to this Clause 6.7(b) for such Liquefaction Train(s), shall be a reduced amount equal to the applicable bonus amount set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule), less the product of the applicable bonus degradation factor set forth in Annex C-1 of Appendix C (Scope of Supply & Project Schedule) (in each case, the “Bonus Degradation Factor”) multiplied by the number of days from the Bonus Date to the later of the actual date of Delivery of such Liquefaction Train to the Delivery Point.

 

  (c)

General dispositions

The Bonus amounts payable under Clauses 6.7(a) and 6.7(b) shall upon payment by Buyer be treated as an increase to the Contract Price for purposes of the Agreement.

If any of the Liquefaction Trains is not delivered to the Delivery Point in its entirety on or before the applicable Delivery Date, then no bonus amount shall be earned or due.

In no event shall the total aggregate amount of all bonus amounts paid by Buyer under this Clause 6.7 exceed [***].

For the purposes of this Clause 6.7 only, Seller shall be deemed to have delivered any Liquefaction Train as described in this Clause 6.7, on or before the Bonus Date notwithstanding that certain minor items forming a part of such Liquefaction Train have not been delivered to Buyer at the Delivery Point by such Bonus Date; provided that (i) the Lender’s Engineer has confirmed to Buyer in writing (upon Buyer’s request) that the absence of such minor items would not reasonably be expected to adversely impact the project schedule for testing, commissioning, safety or operability of such Liquefaction Train, and (ii) all such minor items are delivered to Buyer at the Delivery Point not later than the relevant Delivery Date for such Liquefaction Train in the Project Schedule or such other date as mutually agreed by the Parties in writing. Amounts earned by Seller pursuant to this Clause 6.7 shall be due and payable by Buyer to Seller upon completion of delivery by Seller of the Liquefaction Train System and all Components of Tranche A and Tranche B (as such terms are defined in the PIS Purchase Order) of the power island system in accordance with the PIS Purchase Order and the finalization of a Change Order within [***] days thereof.

 

A-28


7.

CONTRACT PRICE AND PAYMENT

 

7.1

Definition of Contract Price

The Contract Price is equal to the sum of [***]. The Contract Price, payment terms and cancellation schedule/charges for each individual Liquefaction Train is detailed in Appendix B (Pricing; Payment Terms & Cancellation Schedule). The Contract Price shall not include any duties and tariffs paid by Seller to deliver each Liquefaction Train to the Delivery Point (“Duties”) or the physical transportation costs set forth in Appendix K (Transportation Costs), exclusive of insurance costs and taxes associated with physical transportation costs other than Duties for each such Liquefaction Train (“Transportation Costs”). Buyer shall reimburse Seller for all reasonable, documented out-of-pocket Duties and Transportation Costs incurred by Seller, plus a fixed fee of [***], payable in accordance with Appendix B (Pricing; Payment Terms & Cancellation Schedule). The Contract Price does not include any Buyer Taxes. Transportation Costs, inclusive of the fixed fee, shall not exceed in the aggregate an amount equal to the sum of [***], provided that Seller has made commercially reasonable efforts to obtain competitive transportation pricing terms and to minimize transportation costs.

When the amount of Transportation Costs forecast by Seller reaches [***] of the not to exceed amount of Transportation Costs amount set forth above and Seller reasonably estimates that the aggregate Transportation Costs may exceed such not to exceed amount of Transportation Costs, Seller shall notify Buyer and provide an estimate of the remaining Transportation Costs anticipated to complete the deliveries under this Agreement. Buyer will reasonably consider an adjustment to the not to exceed Transportation Costs; provided that any such increase in the Transportation Costs shall be mutually agreed in a Change Order to this Agreement. Buyer hereby agrees to pay the Contract Price to Seller upon completion of the relevant Payment Milestones in accordance with the payment schedule (the “Payment Schedule”) set forth in Appendix B (Pricing; Payment Terms & Cancellation Schedule), in consideration for the performance by Seller of its related obligations under the Agreement.

B. The Contract Price shall be adjusted by an amount equal to the sum of (a) an amount reflecting changes in labor and commodities indices calculated in accordance with Part 1 of Appendix M (Contract Price Adjustments) and (b) a foreign exchange adjustment calculated in accordance with Part 2 of Appendix M (Contract Price Adjustments) between the Effective Date and the date of issuance of LNTP (or the date of issuance of FNTP in the event LNTP is not issued). The adjustments described in this paragraph shall be mutually agreed upon by the Parties in a Change Order as soon as reasonably practicable following issuance of LNTP (or if LNTP is not issued, following the issuance of FNTP for) and availability of Index 1 set forth in Part 1 of Appendix M (Contract Price Adjustments).

C. In the event that LNTP is issued and FNTP is not issued within [***] Days following the issuance of LNTP, then the Contract Price shall be adjusted further by an amount equal to the sum of (a) an amount reflecting changes in labor and commodities indices calculated in accordance with Part 3 of Appendix M (Contract Price Adjustments)

 

A-29


and (b) a foreign exchange adjustment calculated in accordance with Part 4 of Appendix M (Contract Price Adjustments) between the date that is [***] Days after issuance of LNTP and date of issuance of FNTP. The adjustments described in this paragraph shall be mutually agreed upon by the Parties in a Change Order as soon as reasonably practicable following issuance of FNTP and availability of Index 1 set forth in Part 3 of Appendix M (Contract Price Adjustments).

D. Payment of undisputed amounts of the Contract Price owed to Seller shall be made by Buyer thirty (30) Days from Buyer’s receipt of an invoice from Seller following completion of the relevant Payment Milestone(s) and receipt of all the relevant documentation, in accordance with the Agreement, and shall be remitted by wire transfer to the following account:

[***]

 

7.2

Currency

Except as otherwise provided in the Agreement, payment shall be made by Buyer in Dollars, upon the completion of the individual Payment Milestones as set out in the Agreement and after Buyer’s receipt of an invoice for such Payment Milestones, reasonable evidence of the completion of such Payment Milestones, Lien waiver and releases in accordance with Clause 7.6, and other specified documentation required under the Agreement.

 

7.3

Late Payments

Any undisputed amounts due and unpaid by either Party to the other Party shall bear interest commencing when such payment is due at a rate equal to the lesser of (a) [***] above the per annum Prime Rate reported daily in The Wall Street Journal, or (b) the maximum rate permitted by applicable Law, on all amounts not timely paid in accordance with the Agreement. The payment of interest is in addition, and not in lieu, of a Party’s right to suspend its performance or terminate the Agreement, as provided for under the Agreement.

 

A-30


7.4

Payment of Subcontractors

Seller shall pay each Subcontractor, save for disputes between Seller and any Subcontractor, the amount to which Subcontractor is entitled in accordance with the terms and conditions of the Agreement between Seller and such Subcontractor.

 

7.5

Set Off Rights

Each Party shall have the right at any time or from time to time, to set off against any amount due to the other Party under the Agreement any amount due from the other Party under the Agreement, including any amounts due because of breach of the Agreement. Buyer may, after written notice to Seller, withhold payment on an invoice or a portion thereof in the event of a failure of Seller to perform the Payment Milestone related to the payment being requested under such invoice, until such time as such Payment Milestone has been completed by Seller in accordance with the provisions of the Agreement. The written notice to Seller shall reasonably describe the failure of Seller and requirements necessary under the Agreement to complete the Payment Milestone.

 

7.6

Invoice Documentation

As a condition precedent to the obligation of Buyer to make each payment under the Agreement, Seller shall deliver with each invoice for each payment, a partial Lien waiver and release in the form of Appendix J-1 (Seller Form of Partial Lien Waiver and Release) in exchange for the current payment, and a partial Lien waiver and release in the form of Appendix J-3 (Subcontractor Form of Partial Lien Waiver and Release) from each Subcontractor; provided however, if such invoice is the invoice for the final payment under the Agreement, Seller shall be obligated to provide Buyer a final Lien waiver and release in the form of Appendix J-2 (Seller Form of Final Lien Waiver and Release), in exchange for the final payment, and a final Lien waiver and release in the form of Appendix J-4 (Subcontractor Form of Final Lien Waiver and Release) from each such Subcontractor, in exchange for the final payment. In addition to the final Lien waivers and releases from each Subcontractor, Seller shall provide, with such final invoice, an affidavit setting forth: (a) all amounts paid to each Subcontractor; (b) all amounts owed to each Subcontractor, if any; and (c) any amounts in dispute under any subcontract.

 

7.7

No Liens

To the extent that Buyer has timely paid Seller under the Agreement, Seller shall (a) not directly or indirectly create, incur, assume, or suffer to be created by it or any Subcontractor, employee, laborer, materialman, or other supplier of goods or services any Liens on or in respect of a Liquefaction Train, the Site, the Facility or any part thereof or interest therein, or against any party, and (b) promptly pay and/or discharge of record any Lien or other charges that, if unpaid, might be or become a Lien on a Liquefaction Train,

 

A-31


the Site, the Facility or any part thereof or interest therein. Seller shall pay when due all amounts payable for labor and materials furnished in connection with the Agreement to prevent any Lien or other claim in respect of such labor and materials from arising. Seller shall immediately notify Buyer of the assertion of any Lien on a Liquefaction Train, the Site, the Facility or any part thereof or interest therein. Upon the failure of Seller to promptly pay, discharge, or provide security reasonably acceptable to Buyer for any Lien on a Liquefaction Train, the Site, the Facility or any part thereof or interest therein in respect of which Seller has been timely paid in accordance with the Agreement, within ten (10) Working Days of notice of the existence thereof from any source, Buyer may, but shall not be obligated to, pay or discharge such Lien and, upon the payment or discharge thereof, shall be entitled to immediately recover from Seller the amount thereof together with expenses incurred by it in connection with such payment or discharge or to set off all such amounts against any such sums owed by Buyer to Seller under the Agreement.

 

7.8

Buyer Credit Support

Within thirty (30) Days of the Effective Date, Buyer will provide a Buyer Parent Company Guarantee substantially in the form of Appendix D (Form of Buyer Parent Company Guarantee) issued by Buyer’s parent company in favor of Seller and covering Buyer’s payment obligations under the Agreement. The initial Buyer Parent Company Guarantee shall remain valid until the earlier of (i) the assignment of the Agreement to the EPC Contractor in accordance with Clause 4 or (ii) Financial Closing, at which time the Buyer Parent Company Guarantee shall be of no further force and effect and Seller shall return the original Buyer Parent Company Guarantee to Buyer. If the Agreement is assigned by Owner to the EPC Contractor, the EPC Contractor (in its capacity as Buyer) will provide a Buyer Parent Company Guarantee substantially in the form of Appendix D (Form of Buyer Parent Company Guarantee) issued by the EPC Contractor’s parent company in favor of Seller and up to an amount equal to the Contract Price, which Buyer Parent Company Guarantee shall remain valid until receipt by Seller of the final payment of the Contract Price.

 

7.9

Seller Credit Support

Within thirty (30) Days of the Effective Date the Agreement, Seller shall provide a Seller Parent Company Guarantee substantially in the form of Appendix H (Form of Seller Parent Company Guarantee) issued by BHH in favor of Buyer and covering Seller’s obligations under the Agreement. Buyer shall be entitled, in its sole discretion, to make a demand on the Seller Parent Company Guarantee in respect of any failure by Seller to perform hereunder.

 

7.10

Payment Not Acceptance

No partial or final payment made by Buyer shall be construed as a waiver of any breach hereof by Seller or as an acceptance of defective portions of the performance by Seller hereunder or of any of the performance of Seller’s obligations hereunder that does not strictly comply with all requirements of the Agreement.

 

A-32


8.

TAXES AND DUTIES

 

8.1

Seller Taxes; Buyer Taxes

Seller shall be responsible for and shall pay all Seller Taxes. Buyer shall be responsible for and shall pay all Buyer Taxes (or reimburse Seller for Buyer Taxes in the event Seller is required to remit any Buyer Taxes directly to taxing authorities). If Buyer deducts or withholds Seller Taxes from the Contract Price, for each deducted or withheld amount of Seller Taxes, Buyer shall provide Seller, within thirty (30) Days from payment of Seller Taxes, with the official receipt issued by the appropriate Governmental Authority to which Seller Taxes have been paid or an alternative document acceptable to the relevant tax authorities. In respect of taxes to be withheld, if any, Buyer shall comply with any applicable bilateral conventions against double taxation. If Buyer requires tax residence certificates from Seller to apply an exempted or reduced tax regime, Seller shall submit the appropriate certificates, upon Buyer’s written request. If Buyer, under the applicable Laws of any country other than Seller’s country of incorporation, deducts or withholds Seller Taxes, Buyer shall pay additional amounts to Seller so that Seller receives the full amount of the Contract Price, as though no such Seller Taxes had been deducted or withheld.

 

8.2

Exemptions

If either Party benefits from any tax, fee or Duty exemption (a “Benefitted Party”) applicable to the other Party or its Subcontractors (the “Other Party”), such Benefitted Party agrees to provide the Other Party, without charge, before invoicing, or before any other relevant event, documentation acceptable to supporting the tax or customs authorities supporting the exemption, together with instructions for the Other Party on the procedure for the exemption. Pursuant to state Law, certain tax and incentive programs are available to qualifying manufacturers in certain circumstances, including the Louisiana Quality Jobs Program, Enterprise Zone Program, and the Manufacturing Machinery and Equipment sales tax exclusion (collectively, the “Rebatable Louisiana Sales and Use Tax”). Owner has not determined which, if any, of these programs it will pursue. Seller shall cooperate with and assist Buyer and Owner and any designated tax and incentive consultant, and shall require Subcontractors to cooperate with and assist Buyer and Owner and any designated tax and incentive consultant, in obtaining tax and incentive benefits under these and any other available programs. Such assistance may include, but is not limited to, documenting purchase transactions, providing reports and supporting documents required to be submitted to obtain the tax and incentive benefits, and acting as agent for Owner in connection with the purchase of manufacturing machinery and equipment. If the determination of the proper amount of such Rebatable Louisiana Sales and Use Tax assessed on the Seller work is dependent upon knowing the actual cost incurred by Seller or its Subcontractors for the compensation of such Seller work, that portion of the audit devoted to reviewing the actual cost incurred by Seller or its Subcontractors for such Seller work shall be performed by Buyer or Owner’s tax consultant, which shall be retained by Buyer or Owner at Owner’s sole expense. The Parties agree that (unless the amount of Rebatable Louisiana Sales and Use Tax properly payable for the Seller work is subject to

 

A-33


audit, litigation, arbitration, subpoena or summons issued by a Governmental Authority) such tax consultant shall not disclose to Buyer or Owner the actual cost incurred by Seller or its Subcontractors for such work, but the Parties agree that such tax consultant may report to Buyer or Owner the proper Rebatable Louisiana Sales and Use Taxes properly payable under applicable Law. No access to documents shall be granted to Buyer or Owner’s tax consultant until such tax consultant has signed a confidentiality agreement with Seller and any applicable Subcontractor with terms customary in the audit industry for audits of this kind.

 

8.3

No Taxes Included

The Contract Price does not include any Buyer Taxes. Therefore if any Buyer Taxes are required to be collected by Seller, such Buyer Taxes will be added to the Contract Price. For Country sales and use tax, and in other jurisdictions where applicable, Buyer may report or remit sales taxes or similar taxes directly if Buyer timely provides a direct pay or exemption certificate to Seller.

 

8.4

Exemptions for Steel and Aluminum Imports

Seller shall provide all reasonably requested support and assistance to Owner and Buyer related to such filings (including any joint filings by Owner and Seller or its Affiliates) or deliverables that are necessary or appropriate to request an exclusion or exemption from the remedies instituted in Presidential Proclamations Adjusting Imports of Steel Into the United States and Adjusting Imports of Aluminum Into the United States under Section 232 of the Trade Expansion Act of 1962 or similar tariff measures; although Seller does not guarantee that it will achieve any particular results related to Seller’s support so provided. Such assistance may include, but is not limited to, documenting purchase transactions and providing reports and supporting documents required to be submitted to obtain the exclusion or exemption. Without limiting the generality of the foregoing, Seller shall notify Buyer before subcontracting with any Approved Subcontractor located in China in connection with the performance of the Agreement. If and to the extent the same would (to Seller’s knowledge) reasonably be expected to result in Buyer becoming liable hereunder for the payment of additional amounts in relation to tariffs or Duties, Seller shall consult with Buyer in good faith in relation to the selection of an alternative Approved Subcontractor not located in Asia.

 

9.

DELIVERY, TITLE TRANSFER, RISK OF LOSS, STORAGE

 

9.1

Delivery

Seller shall deliver equipment for each Liquefaction Train DDP the marine offloading facility(ies) adjacent to the Site as designated by Buyer to Seller for the items to be delivered by ocean vessel or barge (Incoterms 2020) and DDP the Site for the items to be delivered by truck (Incoterms 2020) (collectively, the “Delivery Point”). Except for those obligations expressly set forth in the applicable Incoterms 2020 or as specifically provided under the Agreement, Seller shall not be liable in any claim asserted by Buyer with respect to delivery of the Liquefaction Trains beyond the Delivery Point.

 

A-34


The date of delivery for each Liquefaction Train is the date on which such Liquefaction Train in its entirety is delivered in accordance with this Clause 9.1 per the Incoterms to the Delivery Point, or if applicable, to a transshipment facility, as shall be directed by Buyer to Seller from time to time and set forth in a Change Order (each, a “Transshipment Facility”). The date of delivery for each Liquefaction Train is the date on which the Liquefaction Train in its entirety is delivered in accordance with this Clause 9.1 per the Incoterms to the Delivery Point; provided it is understood that for the purposes of Clauses 6.4 and 6.7 only, the date on which Seller delivers the modules and MR compressors of such Liquefaction Train to the Transshipment Facility shall be treated as the date on which Seller has delivered such Liquefaction Train to the Delivery Point (as such term is used in Clauses 6.4 and 6.7); and provided, further, for the purposes of Clauses 6.4 and 6.7 only, that each reference to the Delivery Point in Clause 6.4 shall be treated as a reference to both the Transshipment Facility and the Delivery Point. For the avoidance of doubt, delivery of an individual Liquefaction Train for purposes of the Agreement shall occur only when Seller has complied with all of its delivery obligations hereunder for that individual Liquefaction Train in its entirety. Except as otherwise provided in the Project Schedule or authorized in writing by Buyer, Seller shall not deliver the Liquefaction Trains (as provided in the Project Schedule) to the Delivery Point in each case more than [***] prior to the last day on which Buyer, in each case, would be entitled to payment of a bonus pursuant to Clause 6.7.

Upon delivery, Buyer shall unload delivered items within a reasonable time, and for all ocean vessel/barge shipments no later than [***] from delivery.

 

9.2

Seller Replacement of Non-Conforming Items

If after delivery to the Delivery Point, Buyer discovers any item of a Liquefaction Train that has been damaged prior to delivery or that fails to conform with the requirements of the Agreement, then after receiving written notification of such non-conformance, the Seller shall promptly repair or replace such item or items, at Seller’s sole cost and expense in accordance with Clause 17.

 

9.3

Title; Risk of Loss

Title to each item of the Liquefaction Train shall pass from the Seller to the Buyer as follows:

 

  (a)

for each such item shipped from within the United States, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9.4, upon the earlier of (i) when Seller makes such item available for shipment from the warehouse or from the manufacturer’s factory and (ii) payment by Buyer to Seller for such item;

 

A-35


  (b)

for each such item shipped from the European Union, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9.4, upon the earlier of (i) when such item has been cleared for export, or (ii) when such item departs from the territorial land, sea and overlying airspace of the country from which such item is shipped; and

 

  (c)

for each such item shipped from within any other country, directly to the Delivery Point or a mutually agreed storage location selected by the Parties pursuant to Clause 9.4, when such item departs from the territorial land, sea and overlying airspace of the country from which such item is shipped.

Seller shall maintain the risk of loss of each Liquefaction Train until such Liquefaction Train is delivered to the Delivery Point, except as provided in Clause 9.4. Buyer shall only be responsible for risk of loss of each Liquefaction Train once such Liquefaction Train has been properly delivered to the Delivery Point.

 

9.4

Storage Locations

If any Liquefaction Train cannot be delivered to Buyer in accordance with the delivery terms herein due to Buyer’s request or any cause attributable to Buyer or its Affiliates and its or their officers, servants, agents, employees, sub-contractors, suppliers, and/or assigns, including transportation, staging, storage, or shipping service providers, upon notice to Buyer, Seller may ship such Liquefaction Train to a storage location mutually agreed to by Buyer and Seller; provided that Seller is not obligated to store or maintain any Liquefaction Train at Seller’s site past the Delivery Date for such Liquefaction Train. If such Liquefaction Trains are placed in a storage location pursuant to the preceding sentence of this Clause 9.4, the following conditions shall apply: (a) any amount of the Contract Price otherwise payable to Seller upon delivery to the Delivery Point shall be invoiced by Seller and payable by Buyer within thirty (30) Days of receipt by Buyer of such invoice and related documentation, including certification by Seller as to cause for storage; (b) all reasonable and documented incremental expenses incurred by Seller, such as for preparation for and placement into storage, handling, inspection, preservation, insurance, storage, removal charges and any taxes shall be reimbursed by Buyer upon submission of Seller’s invoices and related documentation, including evidence of such incremental expenses; and (c) upon receipt of notice from Buyer and payment of all undisputed amounts due under this Clause 9, Seller shall resume delivery of the Liquefaction Trains to the originally agreed Delivery Point (and any transportation costs or Duties incurred in the transportation of the Liquefaction Trains from storage to the Delivery Point shall not be subject to the limitation on Transportation Costs set forth in Clause 7.1). In the event the storage period extends for longer than [***] Days, the Parties shall reconvene to agree on the schedule to reach delivery. To the extent shipment to storage of any of the Liquefaction Trains causes a delay in Seller’s schedule for delivery of the remaining Liquefaction Trains to be delivered hereunder, then Seller shall have the right to request a Change Order for adjustment of the Delivery Date for such remaining Liquefaction Trains.

 

A-36


10.

SELLER’S OBLIGATIONS

 

10.1

Compliance with Law

Seller shall, in performing its obligations under the Agreement, comply in all respects with all applicable professional standards, permits and Laws, rules, codes and regulations and the Liquefaction Train System shall be in full compliance with all applicable professional standards, permits and Laws, rules, codes and regulations. Seller shall perform its obligations hereunder in accordance with the Project Schedule. Seller shall only use qualified personnel to perform its obligations hereunder. Seller shall be responsible for obtaining all licenses, permits and approvals from all Governmental Authorities that are required for Seller to perform its obligations under the Agreement.

 

11.

BUYER’S OBLIGATIONS

 

11.1

Access to and Possession of the Site

Access to the Site, including the use of Owner’s rights of way and easements, shall be granted to Seller by Buyer, only to the extent necessary and for the sole purpose of Seller performing its obligations under the Agreement.

 

11.2

Access not exclusive

The access to the Site provided by Buyer shall not be exclusive to Seller.

 

11.3

Personnel for Acceptance Tests

When each Liquefaction Train or Liquefaction Train System is ready for any acceptance or testing that is required under Appendix C (Scope of Supply & Project Schedule), Owner and/or Buyer shall provide the normal operating and maintenance personnel under the technical direction and supervision of Seller pursuant to the Services Agreement for such testing. For the avoidance of doubt, Seller’s personnel shall never be deemed to be Buyer’s or Owner’s employees, and vice versa.

 

11.4

Electricity, Water and Gas

Buyer shall be responsible at its own costs for the provision of all utilities, including but not limited to electricity, natural gas and water (including drinking water) for activities necessary to be performed on Site. Buyer shall also be responsible for and bear the costs of all arrangements for connection, metering and distribution.

 

11.5.

Organization on Site

Seller shall cause its personnel and its Subcontractor’s personnel to observe and comply with all safety and security protocols of Buyer when such personnel are on the Site, provided that Seller has been made aware of such safety and security protocols requirements.

 

A-37


12.

DOCUMENTATION BY SELLER

 

12.1

Reports

Seller shall prepare and submit to Buyer at the appropriate time the progress reports as detailed in Appendix C (Scope of Supply & Project Schedule). Seller shall submit all such other information and reports in relation to the Liquefaction Train System as Buyer shall reasonably request from time to time.

 

12.2

Submission of Technical Documentation

Appendix C (Scope of Supply & Project Schedule) specifies which Technical Documentation is to be submitted to Buyer by Seller. Seller shall submit such Technical Documentation to Buyer within the time required in Appendix C (Scope of Supply & Project Schedule). The Technical Documentation is required to be provided by Seller to Buyer. Buyer may give comments on any Technical Documentation submitted within [***] of Buyer’s receipt thereof, unless otherwise mutually agreed by Buyer and Seller, and Seller shall make the appropriate revisions to such Technical Documentation. The Technical Documentation shall include Seller’s standard Operation and Maintenance Manuals and the functional descriptions, in sufficient detail, to enable competent personnel to operate, maintain and repair the Liquefaction Train System.

 

12.3

Errors in Technical Documentation

Seller shall be liable for any Costs incurred in correcting any discrepancies, errors or omissions in the Technical Documentation prepared by it or its Subcontractors or on their behalf.

 

13.

MACHINERY, EQUIPMENT, SPARE PARTS AND WORKMANSHIP

 

13.1

Manner of Execution

The Liquefaction Train System shall be manufactured in the manner set out herein, including Clause 5, and in Appendix C (Scope of Supply & Project Schedule).

 

13.2

Quality of Materials

The Liquefaction Train System shall be brand new and unused, and all parts and components thereof shall be brand new and unused, upon delivery and shall in any event be in accordance with the standards and other requirements set forth in the Agreement.

 

A-38


13.3

Spare Parts

Not later than [***] prior to the Delivery Date of the first Liquefaction Train under the Agreement, Seller shall deliver to Buyer a detailed list and pricing proposal for all Subcontractor and Seller-recommended spare parts for operating and maintaining the Liquefaction Train System (including components and systems of each such Liquefaction Train System) (“Spare Parts”). Within [***] thereafter, Buyer shall specify in writing (via a Change Order) which items on the list of Spare Parts it wishes to purchase and the time (in accordance with Seller’s proposal) when such items should be delivered to a location designated by Buyer. The amount due from Buyer to Seller in connection with Spare Parts shall be based on current market prices.

 

14.

TESTING AND RIGHT TO INSPECT DURING MANUFACTURING

 

14.1

Documents

Seller documents that are included as Deliverables in Appendix C (Scope of Supply & Project Schedule) and annotated with an “A”, including Technical Documentation, shall be submitted to Buyer for approval, in accordance with the Project Schedule. Such documents shall be submitted to Buyer in substantially complete packages for each Liquefaction Train to be delivered hereunder.

 

14.2

Inspection and testing during manufacturing

Each Buyer Inspection Party shall be entitled during the manufacturing of the Liquefaction Train System to inspect and examine the materials and workmanship in accordance with the inspection test plan to be mutually agreed upon in accordance with Appendix C (Scope of Supply & Project Schedule), to attend any scheduled test of the Liquefaction Train System (or major components thereof) on Seller’s premises during working hours, and to check the progress of manufacture of the Liquefaction Train System (or major items thereof) to be supplied under the Agreement during normal business hours. If components of the Liquefaction Train System are being manufactured on other premises, Seller shall, upon receipt of written request from Buyer or Owner, make commercially reasonable efforts to obtain for the Buyer Inspection Parties permission to inspect, examine and attend any test, provided that such inspection, examination or attendance of tests shall not delay the execution of the works (without prejudice to Clause 14.3). Such inspection, examination or attendance of tests, if made, shall not grant access to areas of Seller’s facilities not related to the execution of Seller’s obligations under Appendix C (Scope of Supply & Project Schedule) or where other work of a proprietary nature is being performed.

 

14.3

Dates for inspection and testing

 

  (a)

Each Buyer Inspection Party shall have the right to witness such activity of inspection or testing required in accordance with Appendix C (Scope of Supply & Project Schedule). Buyer and Owner each shall have the right to ask for additional witness points during the manufacturing of the Liquefaction Trains, subject to Seller’s right to request a Change Order for any adverse impact on the delivery of the Liquefaction Trains as a result of such additional witness points.

 

A-39


  (b)

The Parties shall agree (at least thirty (30) Days prior to the proposed date) on the date on, and the place at, which the Liquefaction Train System and/or portion(s)/module(s) will be ready for inspection and/or testing. Should any postponement become necessary, Seller shall provide written notification of the same at least three (3) Working Days prior to the originally scheduled date. Each of Buyer and Owner shall give Seller two (2) Working Days’ notice in writing of its intention to attend the tests or ask for a postponement of not more than twenty-four (24) hours if required.

 

  (c)

Should Buyer or Owner not attend the tests at the place and on the date which Seller has stated in its notice, Seller may proceed with the tests and Seller shall forthwith forward to Buyer and/or Owner the test results together with supporting data and written notice of required corrections, if any, which notice will state each respect in which the equipment is not in conformance with the Agreement, and perform all such corrections to the equipment to ensure that the equipment complies with the Agreement.

 

  (d)

If Buyer or Owner decides, at receipt of the test results, that the test should be repeated in its presence (even though the test results, in the opinion of Seller, were satisfactory), all the consequences of such repeat test (additional Cost and delay suffered by Seller) shall be borne by Buyer, unless such repeat tests give results materially not in accordance with the Agreement, in which case they shall be borne by Seller. If, however, neither Buyer or Owner notifies Seller, within five (5) Working Days after receipt of the test results, that it has decided that the test should be repeated in its presence, Seller shall not be obliged to repeat such test.

 

  (e)

Seller shall provide at least ten (10) Days’ advance notification to Buyer or a third party, acting on Buyer’s behalf, of any inspection or test in accordance with the procedures set forth in Appendix E (Quality Assurance and Quality Control). Buyer and Owner shall have the right to add by written notice to Seller witness points and/or holding points, either for Buyer or Owner or any such third party.

 

14.4

General right to inspect during manufacturing

Each Buyer Inspection Party shall be entitled to inspect the Liquefaction Train System during Seller’s manufacturing at Seller’s facilities, during working hours after having given to Seller a reasonable notice. Any inspection of the Liquefaction Train System by any Buyer Inspection Party shall not release Seller from any obligation under the Agreement nor constitute an acceptance by Buyer or any other party of any portion of the Liquefaction Train System inspected or tested.

 

A-40


14.5

Certificate of testing

As and when the Liquefaction Train System shall have passed the factory acceptance testing referred to in Section 1.6 of Appendix C (Scope of Supply & Project Schedule) during the manufacturing (the “Factory Acceptance Tests”), Seller shall, within thirty (30) days following completion of any Factory Acceptance Test, whether such Factory Acceptance Test passed or failed, provide the factory report with all required supporting data (including any anomalies encountered during the Factory Acceptance Test), signed by Seller and the factory performing such Factory Acceptance Tests and deliver the same to Buyer. All reports and related documentation associated with the Factory Acceptance Tests shall be stored in the manufacturing data books prepared in accordance with Seller’s standard practice, and all such manufacturing data books will be finally delivered to Buyer in electronic form no later than ninety (90) Days after the final Delivery Date.

 

14.6

Failure on tests or inspection

If as a result of any inspection, examination or test of the Liquefaction Train System, Buyer or Owner, as the case may be, shall consider with reasonable justification that the Liquefaction Train System and/or portion(s)/module(s) contain any Defect or is not in accordance with the Agreement, Buyer or Owner, as the case may be, shall notify Seller accordingly stating in writing its objection and reasons therefore. Seller shall promptly investigate Buyer’s or Owner’s claim, and if a Defect is found to exist, Seller shall rework and reperform its obligations under Appendix C (Scope of Supply & Project Schedule) necessary to remedy the Defect and bring the results of Seller’s performance of its obligations under Appendix C (Scope of Supply & Project Schedule) back in conformance with the requirements of the Agreement. Thereafter, if a Defect in any component of a Liquefaction Train is discovered before the delivery of such Liquefaction Train to the Delivery Point, if requested by Buyer or Owner, as the case may be, the necessary tests not passed shall be repeated under the same terms and conditions, provided that all Costs resulting from the repetition of the tests shall be for Seller’s account.

 

14.7

Right to inspect by others

In exercising its rights to inspect the Liquefaction Train System and/or to attend any tests under the Agreement, each of Buyer and Owner shall, upon consent of Seller and at Buyer’s cost, be entitled to be accompanied by any Lenders, Lender’s Engineer, advisor(s) of Buyer, or any adjusters or insurers’ representatives, provided that such accompanying Persons may be first required by Seller to enter a separate non-disclosure agreement with Seller. Seller shall allow all such Persons the same rights of inspection and test attendance as are enjoyed by Buyer or Owner pursuant to the Agreement, whether or not such inspection or attendance is made with Buyer or Owner, provided that such Persons may be first required by Seller to enter a separate non-disclosure agreement with Seller.

 

15.

DELIVERY OF THE LIQUEFACTION TRAINS

 

15.1

Delivery

Unless Buyer shall otherwise direct, no Liquefaction Train shall be delivered except in accordance with the schedule of Delivery Dates in the Project Schedule.

 

A-41


15.2

Packing and Marking

The Liquefaction Train System and/or portion(s)/module(s) shall be packed in boxes/containers or packing/packaging in accordance with Seller’s standards set forth in Appendix C (Scope of Supply & Project Schedule).

 

15.3

Detailed specification and procedure

On or before ten (10) Days prior to the Delivery Date of a component of a Liquefaction Train, Seller shall prepare and submit to Buyer, for information and approval, the detailed specification of packing and marking, specify the type and number of documents to be prepared and transmitted, with the form for each of them, all in accordance with the Agreement. Not less than ninety (90) Days prior to the first Delivery Date, the Parties shall meet and discuss the shipping procedures, including marking, cargo list preservation, preservation requirements and other related matters. With respect to equipment identified by either Party as suitable for direct delivery to or offloading at the Delivery Point, Seller shall consult with Buyer in advance of vessel reservation, and the Parties shall mutually agree on reasonably acceptable selection criteria with respect to the vessels to be used for such direct deliveries or offloading.

 

15.4

Warranty of ownership

Seller warrants and guarantees title to the Liquefaction Train System provided under the Agreement, and Seller warrants and guarantees that title and ownership thereto shall pass to and vest in Buyer, as agreed in the Agreement, free and clear of any and all Liens.

 

16.

COMPLIANCE WITH LAWS, CODES AND STANDARDS

 

16.1

Contract Price Basis

The Contract Price is based on Seller’s design, manufacture, testing and delivery of the Liquefaction Train System pursuant to:

 

  (a)

Seller’s design criteria, manufacturing processes and procedures and quality assurance program;

 

  (b)

those industry specifications, codes and standards that are (i) identified in Appendix C (Scope of Supply & Project Schedule) or (ii) otherwise applicable to the Liquefaction Train System or Seller’s obligations under the Agreement;

 

  (c)

those Laws in effect as of the Effective Date, which are applicable to the Liquefaction Train System or Seller’s obligations under the Agreement; and

 

  (d)

the specifications and other requirements contained in the Agreement, including Appendix C (Scope of Supply & Project Schedule).

 

A-42


16.2

Export Controls

The Parties agree to comply with all applicable export control and economic sanctions Laws in the performance of the Agreement, including any restrictions or conditions regarding the export, re-export, or other transfer of the Deliverables under the Agreement that are in effect now or are hereafter imposed by the any Governmental Authority. Each Party shall be responsible for its own compliance with applicable export control and economic sanctions Laws with regards to their Affiliates, employees, facilities and activities. These restrictions and conditions include, but are not limited to, (a) restrictions and export licensing requirements governing the export, re-export, or other transfer to other persons, entities, or countries of the Deliverables under the Agreement, (b) restrictions and export licensing requirements governing the export or other transfer of foreign-developed information that incorporates the Deliverables under the Agreement, (c) any applicable restrictions on the export, re-export, or other transfer of the Deliverables under the Agreement to countries and Persons that are subject to applicable sanctions, embargoes, or other prohibitions, and (d) any applicable restrictions on the export or other transfer of the direct product of technical data. Each Party shall notify the other Party in writing prior to transferring any commodity, software or technology that is: (i) controlled at a level greater than EAR99 or Anti-Terrorism controls under the Export Administration Regulations (“EAR”); or (ii) subject to the jurisdiction of an export control regime other than the EAR. Seller acknowledges that, in connection with the performance of the Agreement, the export and customs Laws and regulations of the Country apply to the furnishing and shipment of the Liquefaction Train System.

 

16.3

Nuclear Activity Restrictions

The Liquefaction Train System sold hereunder is not intended for application (and shall not be used) in connection with any nuclear installation or activity and Buyer warrants that it shall not use the Liquefaction Train System for such purposes, or permit others to use or permit others to use the Liquefaction Train System for any such purposes. If, in breach of the foregoing, any such use of the Liquefaction Train System sold hereunder occurs, Seller shall have no liability for any nuclear or other damage, injury or contamination, and Buyer shall indemnify Seller, its Affiliates and suppliers of every type and tier against any such liability, whether arising as a result of breach of contract, warranty, indemnity, tort (including negligence), strict liability or otherwise.

 

16.4

Required Authorizations

Notwithstanding any other provisions herein, Seller shall be responsible for timely obtaining of any required authorization, such as an import license, foreign exchange permit, work permit or any other authorization from a Governmental Authority that are required for Seller to perform its obligations under the Agreement.

 

A-43


16.5

Anti – Corruption

 

  (a)

Each Party represents, warrants and covenants to the other Party that neither the representing Party, nor any of its Affiliates (or any of their respective principals, partners or funding sources), is currently (i) a Person designated by the U.S. Department of Treasury’s Office of Foreign Assets Control as a “specially designated national or blocked person” (“SDN”) or similar status, (ii) a person otherwise identified by a government or legal authority as a person with whom the other Party is prohibited from transacting business; (iii) directly or indirectly owned or controlled by an SDN or the government of any country that is subject to an embargo by the government of the Country; or (iv) a Person acting on behalf of an SDN or a government of any country that is subject to an embargo by the government of the Country. Each Party agrees that it will notify the other Party in writing immediately upon the occurrence of any event that subsequently results in any of the designations set forth in this Clause 16.5(a).

 

  (b)

Each Party shall, in the performance of the Agreement, comply with all Laws, orders, directives, and regulations in effect on the Effective Date and as they may be amended from time to time that are applicable to such Party. Notwithstanding anything contained herein to the contrary, the Agreement shall not be interpreted or applied so as to require either Party to do, or to refrain from doing, anything that would constitute a violation of federal or state laws and regulations applicable to it, including the Foreign Corrupt Practices Act of 1977, 15 U.S.C. § 78dd-2, the OECD Anti-Bribery Convention, the U.K. Bribery Act of 2010, E.U. and E.U. member country anti-bribery and corruption laws, laws or regulations restricting participation in or compliance with certain foreign boycotts, directly or indirectly, as contained in the U.S. Export Administration Act of 1979, the U.S. Internal Revenue Code or any similar statute, regulation, order or convention binding on such Party, as each may be amended from time to time, and including implementing regulations promulgated pursuant thereto (collectively, the “Anti-Corruption Laws”). Without limiting the foregoing, each Party agrees on behalf of itself, its Affiliates and their respective directors, officers, employees, agents and contractors, not to pay any fees, commissions or rebates to any employee, officer or agent of the other Party or its Affiliates or their respective shareholders, or provide or cause to be provided to any of them any gifts or entertainment of significant cost or value in connection with the Agreement or in order to influence or induce any actions or inactions in connection with the commercial activities of the Parties in connection with the Agreement.

 

  (c)

Each Party represents, warrants and covenants with respect to itself and its Affiliates that (i) it and its Affiliates are being and have been operated in compliance in all material respects with the Anti-Corruption Laws, (ii) neither it nor any of its Affiliates has received any written notice or claim alleging any material violation under any of the Anti-Corruption Laws, and (iii) neither it nor any of its Affiliates, nor any of their respective directors, officers, or employees (or, to the best of the representing Party’s knowledge and belief, any partner, intermediary or other Person acting or purporting to act on behalf of such Party or any of its Affiliates) has knowingly directly or indirectly paid, offered, given, promised to pay or authorized the payment of any money or anything of value to (A) any candidate for public office, any past or present employee, director, officer, official, representative or agent of any government, government or legal authority,

 

A-44


  instrumentality, or any public international organization (“Government Official”), (B) any Person acting for or on behalf of any Government Official, or (C) any other Person at the suggestion, request, direction or for the benefit of any of the above-described Persons to obtain, retain or direct business or to obtain special concessions or pay for favorable treatment for business secured or for special concessions already obtained.

 

  (d)

Neither Seller, nor any of its Affiliates, directors, officers, employees or agents, shall use its relationship with Buyer to attempt to disguise the sources of illegally-obtained funds. Seller further represents and warrants that no such attempt of the sort described in this Clause 16.5(d) has been made prior to the Effective Date.

 

  (e)

Each Party shall keep all records necessary to confirm compliance with this Clause 16.5 for a period of five (5) years following the year for which such records apply. If a Party asserts that the other Party is not in compliance with this Clause 16.5, the asserting Party shall notify the other Party indicating the type of non-compliance asserted. After such notification, the asserting Party may cause an independent auditor to audit the records of the other Party in respect of the asserted non-compliance. The costs of any independent auditor under this Clause 16.5(e) shall be paid (i) by the audited Party, if such Party is determined not to be in compliance with this Clause 16.5 or (ii) by the asserting Party, if the other Party is determined to be in compliance with this Clause 16.5.

 

  (f)

Seller agrees to indemnify, defend, release and hold Buyer, Buyer’s Parties and its and their shareholders, directors, officers, employees, agents, consultants or representatives harmless from any penalties and fines assessed by government authorities arising out Seller’s breach of any or all of this Clause 16.5. Buyer agrees to indemnify, defend, release and hold Seller Parties harmless from any penalties and fines assessed by government authorities arising out Buyer’s breach of any or all of this Clause 16.5. Any breach of any of the representations, warranties and covenants in this Clause 16.5 shall be grounds for termination of the Agreement, and if Seller is the breaching Party, there shall be no further payments due to Seller upon termination.

 

17.

WARRANTY

 

17.1

Warranty; Warranty Period

 

  (a)

Seller warrants to Buyer that (i) each Liquefaction Train shall be (A) free from defects in material, workmanship and title and (B) designed, engineered and manufactured in accordance with applicable Laws, the specifications referenced in the Agreement and the other requirements of the Agreement, and (ii) the performance by Seller of its obligations under Appendix C (Scope of Supply & Project Schedule) shall be free from defects and performed in accordance with applicable Laws and the other requirements of the Agreement. Except as set forth in Clause 17.2, the “Warranty Period” for the warranties in this Clause 17.1 shall

 

A-45


  be the period starting on the date of Substantial Completion of the Liquefaction Train for the [***] Liquefaction Train and ending upon the earlier of (1) [***] after the date of Substantial Completion of the Liquefaction Train System, and (2) [***] from the date that Seller delivered the applicable Liquefaction Train to the Delivery Point, provided that Buyer and Seller shall enter into the Preservation Agreement, for any Liquefaction Trains that are shipped to storage, if the storage period is for a period greater than [***].

 

  (b)

Buyer may, from time to time during the Warranty Period, issue a Change Order (and Seller shall execute such Change Order) extending the Warranty Period for one (1) or more Liquefaction Trains for the number of months specified in such Change Order such total extension not to exceed [***]. Such Change Order shall increase the Contract Price by an amount equal to [***] per Month for each Month that the Warranty Period for [***] Liquefaction Trains is extended by Buyer pursuant to the preceding sentence.

 

17.2

Remedial Actions

 

  (a)

If a failure to meet any of the warranties set forth in Clause 17.1 appears within the Warranty Period, Buyer shall promptly notify Seller in writing and make the defective component available for correction/inspection within a commercially reasonably time period thereafter. Seller, at its expense, shall thereafter correct any Defect by: (i) re-performing the defective performance of its obligations under Appendix C (Scope of Supply & Project Schedule); and (ii) repairing or replacing the defective Liquefaction Train System(s) or components thereof. Seller shall not be responsible for material removal or replacement of systems, structures or other parts of the Facility to grant Seller access to the Liquefaction Train System. Any repair, replacement or re-performance by Seller hereunder shall extend the applicable Warranty Period on such repaired, replaced or re-performed component of the Liquefaction Train System for a period of [***], provided that in no event shall the Warranty Period extend beyond [***] from the date of Substantial Completion of the Liquefaction Train System. Such warranty extension is in lieu of and not in addition to the extension of the Warranty Period for Serial Defects contemplated in Clause 17.2(c).

 

  (b)

Seller shall not be liable for Defects that arise after the Warranty Period, as extended hereunder, has expired. The testing of any replaced or repaired parts of the Liquefaction Train System, equipment or components shall be performed in the same manner as originally contemplated under the Agreement, and Buyer shall be notified of and may be represented at all tests that may be made. Seller shall not be responsible for the removal or replacement of any systems, structures or other parts of Buyer’s facility, which were not provided by Seller, in order for Seller to gain access to the Liquefaction Train System.

 

A-46


  (c)

If, prior to the expiration of the Warranty Period, [***] of the same component of the Liquefaction Train System experience a Defect of an identical or nearly identical nature that causes or could reasonably be expected to cause an outage of a Liquefaction Train (herein, a “Serial Defect”), then Seller shall examine the cause of the Serial Defect and (i) undertake technical analysis of the underlying problem in order to determine (A) the root cause of such Serial Defect and (B) the repairs or replacements that may be required to avoid future occurrences of such Serial Defect, (ii) prepare and provide to Buyer and Owner a written report setting forth the results of such analysis, (iii) promptly redesign if necessary and repair or replace any Liquefaction Train, as necessary, and (iv) if such Serial Defect root cause requires redesign, repair or replacement of the defective component or Liquefaction Train, extend the Warranty Period for such redesigned, repaired or replaced component for an additional period of [***], all at no additional cost to Buyer or Owner. Such warranty extension for Serial Defects is in lieu of and not in addition to the extension of the Warranty Period contemplated in Clause 17.2(a).

 

  (d)

If Seller fails to commence the corrective work for any Defects, Serial Defects or damage within a reasonable period of time not to exceed [***] after receiving notification by Buyer or Owner regarding such Defect, Serial Defect or damage, Buyer or Owner, at their sole discretion, may (in addition to any other remedies that each of them have under the Agreement) proceed to commence to correct such Defect, Serial Defect or damage at Seller’s risk and expense and the Costs incurred by Buyer or Owner, as the case may be, in performing such corrective work shall be paid by Seller.

 

17.3

Warranty Conditions

Seller does not warrant the Liquefaction Train System or any repaired or replaced parts against normal wear and tear or from the involvement in an accident. The warranties and remedies set forth herein are further conditioned upon:

 

  (a)

the proper storage (to the extent it is the responsibility of Buyer or its Affiliates and its or their officers, servants, agents, employees, sub-contractors, suppliers, and/or assigns, including transportation, staging or storage, or shipping service providers), installation, operation, and maintenance of the Liquefaction Train System in conformance with the operation instruction and installation manuals (including revisions thereto) provided by Seller; and

 

  (b)

repair or modification of the Liquefaction Train System pursuant to Seller’s instructions or approval.

Seller does not warrant any equipment or services of others designated by Buyer where such equipment or services are not normally supplied by Seller.

 

A-47


17.4

Warranties Exclusive

[***], THE PRECEDING PARAGRAPHS OF THIS CLAUSE 17 SET FORTH THE EXCLUSIVE REMEDIES FOR ALL CLAIMS BASED ON FAILURE OF OR DEFECT IN THE LIQUEFACTION TRAIN SYSTEM OR PERFORMANCE OF SELLER’S OBLIGATIONS UNDER APPENDIX C (SCOPE OF SUPPLY) PROVIDED UNDER THE AGREEMENT, WHETHER THE FAILURE OR DEFECT ARISES BEFORE OR DURING THE WARRANTY PERIOD AND WHETHER A CLAIM, HOWEVER INSTITUTED, IS BASED ON CONTRACT, INDEMNITY, WARRANTY, TORT/EXTRA-CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY OR OTHERWISE. THE FOREGOING WARRANTIES ARE EXCLUSIVE AND ARE IN LIEU OF ALL OTHER WARRANTIES, CONDITIONS AND GUARANTEES WHETHER WRITTEN, ORAL, IMPLIED OR STATUTORY. NO IMPLIED STATUTORY WARRANTY OR MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE SHALL APPLY.

 

18.

INTELLECTUAL PROPERTY

 

18.1

Work Product

Any concept, idea, product, process, technique, discovery, improvement, know-how, work of authorship (including without limitation documents, specifications, calculations, maps, sketches, notes, reports, data, models, samples, drawings, designs, videos and electronic software) or other information, including the Technical Documentation, in each case whether subject to copyright registration or patent protection or not, other than Seller Developed Intellectual Property, that was first conceived, reduced to practice or created by Seller or any of its employees or Subcontractors in the performance of its obligations hereunder and (a) was furnished by Seller to Buyer as a Deliverable under the Agreement or (b) is an improvement to or otherwise incorporates Buyer’s Background Intellectual Property or Buyer’s Developed Intellectual Property (collectively, “Work Product”) shall be the sole property of Buyer. Seller agrees to assign and hereby assigns to Buyer all rights, title and interest throughout the world in and to all Work Product, including all Intellectual Property therein.

 

18.2

Background Intellectual Property

As between the Parties, each Party exclusively owns all right, title, interest in the Background Intellectual Property created or acquired by it. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty-free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses to the rights granted to Buyer under this Clause 18.2 and to freely transfer the rights granted to Buyer under this Clause 18.2 to third parties, other than to Seller’s Competitors) [***].

 

A-48


Seller expressly reserves all other rights in Seller Background Intellectual Property. Buyer hereby grants to Seller and Seller’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights [***].

 

18.3

Seller Developed Intellectual Property

As between Seller and Buyer, all improvements to the Background Intellectual Property of Seller that are first conceived, reduced to practice or created by Seller or any of its employees or Subcontractors in the performance of Seller’s obligations under the Agreement (the “Seller Developed Intellectual Property”) shall be owned by Seller, subject to Buyer’s rights in any Background Intellectual Property of Buyer contained therein. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses and to freely transfer the rights granted to Buyer under this Clause 18.3 to third parties other than the Seller Competitors) [***]. Seller expressly reserves all other rights in Seller Developed Intellectual Property.

 

18.4

Buyer Developed Intellectual Property

As between Seller and Buyer, all improvements to the Background Intellectual Property of Buyer that are first conceived, reduced to practice or created by Buyer or any of its employees, contractors or consultants in the performance of Buyer’s obligations under the Agreement (the “Buyer Developed Intellectual Property”) shall be owned by Buyer, subject to Seller’s rights in any Background Intellectual Property of Seller contained therein.

 

18.5

Instruments of Service

All reports, design drawings, specifications, field data and notes, calculations, estimates and other documents prepared in the performance of Seller’s obligations under the Agreement by Seller or any of its employees or Subcontractors as instruments of service, other than any such items that are Work Product and other than any items that include Buyer Developed Intellectual Property and/or Buyer’s Background Intellectual Property (collectively, the “Instruments of Service”), shall remain Seller’s property. Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights [***].

 

A-49


18.6

Outside Intellectual Property

(a) Seller shall not use any trade secret, invention, work of authorship, software, patent or protectable design conceived or developed by a party other than Buyer or Seller (collectively, the “Outside Intellectual Property”) in connection with the Agreement unless Seller has secured the rights to use such Outside Intellectual Property for the benefit of Buyer. To the extent Seller uses such Outside Intellectual Property in connection with the Agreement and to the extent that Seller has the legal and contractual right to do so, Seller hereby grants to Buyer and Buyer’s Affiliates perpetual, irrevocable, royalty free, transferable, worldwide, fully paid-up, non-exclusive license rights (including the right to grant sub-licenses to the rights granted to Buyer under this Clause 18.6 and to freely transfer the rights granted to Buyer under this Clause 18.6 to third parties) [***].

(b) Upon Buyer’s request, Seller agrees to provide, without any additional charge, a copy of the Exchanger Design and Rating native file for the dynamic simulation of the Liquefaction Train (the “EDR File”) generated by the supplier of the Cold Boxes. Subject to Clause 22, Buyer shall have the right to use the EDR File for the sole purpose of (i) [***], and (ii) [***]. Except for the use rights set forth herein, nothing in the Agreement is deemed to grant or transfer any Intellectual Property Rights in the EDR File to Buyer. The EDR File shall not be considered a Deliverable and shall be provided by Seller “AS IS” without warranties of any kind.

 

18.7

Restrictions on Use

Except to the extent required by applicable Law, copies of any Work Product, Seller Developed Intellectual Property or Instruments of Service shall not be released to any other party by Seller, or to any Seller Competitors, or used by Seller for any purpose that is unrelated to the Facility, except in response to a subpoena, court order or other legal process, or to the extent that the foregoing materials were already within the public domain

 

A-50


or in the possession of third parties, without the prior written approval of Buyer, which Buyer may withhold in its sole and absolute discretion and excepting that the Parties agree that the restrictions on use in this Clause 18 shall not preclude Seller from using, and Buyer specifically agrees, that Seller retains rights to use (including on subsequent projects or scopes of work with third parties) the Seller’s Know-How, Seller Developed Intellectual Property and Instruments of Service, but subject to the confidentiality obligations set forth in Clause 22. At the expiration or earlier termination of the Agreement, Seller shall promptly deliver to Buyer (but in any event, no later than thirty (30) Days from the date of such expiration or termination) all of the Work Product in all forms and formats including without limitation hard copies and electronic files on disks.

 

18.8

Notification and Indemnification

If either Party is made the subject of any Intellectual Property Claim, such Party shall promptly notify the other Party in writing. Buyer shall defend and indemnify Seller against those Intellectual Property Claims only to the extent that Seller’s allegedly infringing or misappropriating conduct is expressly requested in writing by Buyer. This indemnity shall not extend to any conduct of Seller which is discretionary to Seller. Seller shall defend, indemnify and hold the Buyer Parties harmless against any Losses arising from any Intellectual Property Claim. In no event shall Seller have such indemnity obligations for any Intellectual Property Claim arising from or in connection with any material modification by Buyer that was not authorized by Seller. Buyer shall (a) promptly notify Seller in writing of its receipt of such Intellectual Property Claim and (b) make no admission of liability and (c) not take any position materially adverse to Seller regarding such Intellectual Property Claim. Without limiting the foregoing, Seller shall, at its own expense and option, promptly, but in no event later than thirty (30) Days following the date of notice from Buyer (i) settle or defend the claim or any suit or proceeding and pay all damages and costs awarded in it against Buyer, (ii) procure for Buyer or reimburse Buyer for procuring, the right to continue using the deliverables from Seller’s performance of its obligations under the Agreement, including the infringing service, the Technical Documentation, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim, (iii) modify such infringing deliverables, including the Technical Documentation, service, materials, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim so that they become non-infringing or (iv) replace the infringing deliverables, including any Technical Documentation, service, materials, Work Product, or other Intellectual Property giving rise to such Intellectual Property Claim with non-infringing deliverables to the satisfaction of Buyer; provided that in no case shall Seller take any action which adversely affects Buyer’s continued use and enjoyment of the applicable service, materials, Work Product, or other Intellectual Property without the prior written consent of Buyer. Buyer’s acceptance of the materials, Deliverables, Work Product, and other equipment or any other component of Seller’s performance under the Agreement shall not be construed to relieve Seller of any obligation hereunder. The Buyer Parties agree to cooperate and assist Seller in the defense of any Intellectual Property Claims, at Seller’s cost. Any Buyer Party which seeks to settle any Intellectual Property Claim shall seek the prior approval of Seller, which approval shall not be unreasonably withheld, conditioned, or delayed, in respect of such settlement.

 

A-51


18.9

Seller Simulation Models

Upon Buyer’s request, Seller agrees to provide, if and when requested by Buyer, without any additional charge, one permit for permission based access to Seller’s web-based service that provides access to a copy of the Liquefaction Train transient simulation model created, conceived or developed by Seller or any of its employees or Subcontractors based on a Subcontractor proprietary software named [***] (the “BH-Transient Liquefaction Train Simulation Model”), and, subject to Clause 22, Seller hereby grants to Buyer and Buyer’s Affiliates a, royalty free, non-transferable, non-sublicensable, worldwide, fully paid-up, non-exclusive license [***]. The BH-Transient Liquefaction Train Simulation Model shall not be considered a Deliverable and shall be provided by Seller “AS IS” without warranties of any kind.

 

18.10

Survival

The provisions of Clause 18 shall survive the completion or early termination of the Agreement.

 

19.

INDEMNITY AND LIMITATION OF LIABILITY

 

19.1

Indemnification

 

  (a)

Seller shall indemnify, defend, release and hold harmless the Buyer Parties from any physical damage to property of third parties or injury to Persons, including death, to the extent resulting directly from the negligence or willful misconduct of Seller or its officers, servants, agents, employees, and/or assigns while engaged in activities relating to the Agreement. Buyer shall indemnify, defend, release and hold harmless the Seller Parties from any physical damage to property of third parties or injury to Persons, including death, to the extent resulting directly from the negligence or willful misconduct of Buyer, its officers, servants, agents, employees, and or assigns, while engaged in activities relating to the Agreement.

 

A-52


  In the event such damage or injury is caused by the joint or concurrent negligence of Seller and Buyer, the loss shall be borne by each Party in proportion to its negligence.

 

  (b)

For the purposes of this Clause 19.1 no portion of the Facility or the Site shall be considered third party property and Buyer and Owner release claims related to property damage to the Facility or the Site caused by Seller (and including those property damage claims caused by Seller’s negligence or willful misconduct); provided, however, Seller shall, to the extent directly caused by the negligence or willful misconduct of Seller, be responsible to Buyer and Owner (subject to the limitations of Clause 19.2 and Clause 19.3) for: [***].

 

19.2

Limit of Liability

EXCEPT, WITH RESPECT TO [***], THE TOTAL LIABILITY OF EACH PARTY FOR ALL CLAIMS OF ANY KIND, WHETHER IN CONTRACT, WARRANTY, INDEMNITY, TORT/EXTRA-CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY, OR OTHERWISE, ARISING OUT OF OR RELATING TO THE PERFORMANCE OR BREACH OF THE AGREEMENT OR USE OF THE LIQUEFACTION TRAIN SYSTEM, SHALL NOT EXCEED [***]. BUYER’S PAYMENT OF THE CONTRACT PRICE SHALL NOT COUNT TOWARDS BUYER’S CONTRACT PRICE LIMIT OF LIABILITY HEREUNDER. FURTHER, WITH RESPECT TO SELLER’S FAILURE TO ACHIEVE (1) EACH OF THE LIQUEFACTION TRAIN PERFORMANCE GUARANTEES AND (2) EACH OF THE LIQUEFACTION TRAIN SYSTEM PERFORMANCE GUARANTEES, BUYER AGREES, AFTER ANY TERMINATION OF THE AGREEMENT BY BUYER, NOT TO ASSERT ANY CLAIMS AGAINST SELLER FOR MONETARY DAMAGES IN EXCESS OF [***]. FOR THE AVOIDANCE OF DOUBT, SELLER’S OBLIGATIONS UNDER A CLAIM FOR SPECIFIC PERFORMANCE ARE NOT LIMITED BY THIS CLAUSE 19.2.

 

A-53


19.3

Waiver of Consequential Damages

IN NO EVENT, WHETHER AS A RESULT OF BREACH OF CONTRACT, WARRANTY, INDEMNITY, TORT/EXTRA CONTRACTUAL LIABILITY (INCLUDING NEGLIGENCE), STRICT LIABILITY, OR OTHERWISE, SHALL EITHER PARTY OR ITS SUBCONTRACTORS OR SUPPLIERS BE LIABLE FOR LOSS OF PROFIT OR REVENUES, LOSS OF USE OF THE LIQUEFACTION TRAIN SYSTEM OR ANY ASSOCIATED EQUIPMENT, DOWNTIME COSTS, CLAIMS OF A PARTY’S CUSTOMERS FOR SUCH DAMAGES, OR FOR ANY SPECIAL, CONSEQUENTIAL, INCIDENTAL, INDIRECT OR EXEMPLARY DAMAGES. THE WAIVERS SET FORTH IN THIS CLAUSE 19.3 SHALL NOT APPLY TO LIQUIDATED DAMAGES OR ANY THIRD PARTY INDEMNIFICATION CLAIMS UNDER THE AGREEMENT, PROVIDED THAT EACH OF THE SELLER EXCLUDED PARTIES AND BUYER EXCLUDED PARTIES SHALL NOT BE DEEMED A THIRD PARTY FOR THE PURPOSES OF THIS CLAUSE 19.3.

 

19.4

Seller Protection from Third Parties

If Buyer is furnishing Seller’s Liquefaction Train System to a third party by contract or using Seller’s Liquefaction Train System at a facility owned by a third party, Buyer shall [***].

 

20.

DISPUTE RESOLUTION

 

20.1

Disputes

Any dispute, controversy or claim between the Parties that arises out of, under or in connection with the Agreement, including its interpretation, performance, enforcement, termination, validity or breach (each a “Dispute”) shall be subject to resolution under this Clause 20, which shall be the exclusive dispute resolution method for any such Dispute. A Party wishing to declare a Dispute shall deliver to the other Party a notice identifying the disputed issue (a “Notice of Dispute”). Following the delivery of a Notice of Dispute, the Parties shall attempt in good faith to resolve such Dispute promptly through negotiation. If the Dispute has not been resolved within thirty (30) Days after the date on which the Notice of Dispute was delivered, then any Party shall be permitted to submit such Dispute to binding arbitration in accordance with Clause 20.2.

 

A-54


20.2

Arbitration

Any Dispute that is not resolved pursuant to Clause 20.1 shall be exclusively and definitively resolved through final and binding arbitration conducted in accordance with the Rules of Arbitration of the International Chamber of Commerce (the “ICC Rules”), which (except as modified by this Clause 20.2) are deemed to be incorporated by reference into this Clause 20.2.

 

  (a)

The arbitration tribunal shall consist of three (3) arbitrators. One (1) arbitrator shall be appointed by Buyer, one (1) arbitrator shall be appointed by Seller, and the third arbitrator shall be selected by agreement of the first two (2) arbitrators. If either of the first two (2) appointments is not made within thirty (30) Days after the request for arbitration, or if the first two (2) arbitrators fail to agree on a third arbitrator within thirty (30) Days after the later of them has been appointed, the unfilled appointment will be made, at the request of either Party, by the ICC. No arbitrator appointed pursuant to this Clause 20.2(a) shall be an employee, agent, contractor, competitor or former employee, agent or contractor of, or have or have had any material interest (directly or indirectly) in the business of or in any Party or any of its Affiliates. Each arbitrator shall be knowledgeable with respect to engineering, procurement and construction contracts and shall be fluent in the English language.

 

  (b)

Unless the Parties agree in writing otherwise:

 

  (i)

the seat of arbitration shall be New York, New York, and the language to be used in the proceedings shall be English;

 

  (ii)

the arbitrators shall, by majority vote, render a written award stating the reasons for their award within three (3) Months after any hearing conducted has been concluded. The arbitral award may contain such orders (including orders for specific performance, setoff, other equitable relief or monetary damages) in respect of or affecting any of the Parties (and/or any direct loss or damage suffered by any of them), as such arbitrators determine to be appropriate in the circumstances; provided that, except as expressly permitted by the terms of the Agreement, the arbitrators shall not have the authority to award any indirect, consequential or punitive damages;

 

  (iii)

the Parties and the arbitral tribunal will ensure that the arbitration proceedings and any documents disclosed in such proceedings are kept strictly confidential; and

 

  (iv)

the responsibility for the costs of the arbitration will be determined by the arbitral tribunal.

 

  (c)

An arbitral award rendered in accordance with this Clause 20.2 shall be final and binding on the Parties. The Parties agree that any arbitral award made pursuant to this Clause 20.2 may be enforced against the Parties or their assets wherever they may be found and that a judgment upon the arbitral award may be entered (and any other applicable relief, including interlocutory relief, may be granted) in any court having jurisdiction on such matters, and subject to their respective obligations

 

A-55


  contained elsewhere in the Agreement, shall take all such actions as are necessary to give full and complete effect to the award which, in accordance with its terms, shall be binding upon and enforceable against them. The Parties may make an application to any court for the obtaining of any evidence (whether by discovery of documents, interrogatories, affidavits or testimony of witnesses or whatsoever), which the arbitrators direct shall be admitted in the arbitral proceedings.

 

  (d)

No Party shall be entitled to suspend its performance under the Agreement during the pendency of any Dispute or during the period during which any defaulting Party is attempting to remedy its non-performance of the Agreement within the periods prescribed therefor in Clause 28.

 

  (e)

Nothing contained in this Clause 20 shall be construed to prohibit any Party from making an application to any court of competent jurisdiction for an order of specific performance or for other injunctive or equitable relief as long as the arbitral tribunal contemplated in Clause 20.2 has not yet been formed.

 

20.3

No Consolidation

Unless the Parties otherwise agree, no dispute, controversy or claim hereunder shall be consolidated with any other arbitration proceeding involving any third party.

 

21.

GOVERNING LAW

The validity, construction and performance of the Agreement shall be governed by and construed in accordance with the laws of the State of New York, without regard to the conflict of law provisions thereof that would require the application of the laws of any other jurisdiction.

 

22.

CONFIDENTIALITY

 

22.1

Confidential Information

In connection with the Agreement, each Party (as to information disclosed, the “Disclosing Party”) may each provide the other Party (as to information received, the “Receiving Party”) with Confidential Information. “Confidential Information” means:

 

  (a)

all pricing for Liquefaction Train System;

 

  (b)

all information that is designated in writing as “confidential” or “proprietary” by Disclosing Party at the time of written disclosure, except Work Product; and

 

  (c)

all information that is orally designated as “confidential” or “proprietary” by Disclosing Party at the time of oral disclosure and is confirmed to be “confidential” or “proprietary” in writing within ten (10) Days after oral disclosure, except Work Product.

 

A-56


Any Confidential Information disclosed or revealed by the Disclosing Party shall remain the Disclosing Party’s property and the Receiving Party shall not use such Confidential Information for its own benefit or for the benefit of any third party nor shall the Receiving Party disclose to any third party any such Confidential Information disclosed or revealed to it by the Disclosing Party, except as permitted under the Agreement. The Receiving Party shall take every reasonable precaution to protect the confidentiality of Confidential Information.

The obligations of this Clause 22.1 shall not apply as to any portion of the Confidential Information that:

 

  (i)

is or becomes generally available to the public other than from disclosure by Receiving Party, its representatives or its Affiliates;

 

  (ii)

is or becomes available to Receiving Party or its representatives or Affiliates on a non-confidential basis from a source other than Disclosing Party when the source is not, to the best of Receiving Party’s knowledge, subject to a confidentiality obligation to Disclosing Party;

 

  (iii)

is independently developed by Receiving Party, its representatives or Affiliates, without reference to the Confidential Information;

 

  (iv)

is required to be disclosed by Law, a valid legal process or a Governmental Authority;

 

  (v)

is approved for disclosure in writing by an authorized representative of Disclosing Party;

 

  (vi)

is disclosed by Seller to its Affiliates and each of their agents, advisors, employees, consultants, contractors, officers, directors and representatives (collectively, the “Seller’s Representatives”) to the extent necessary to evaluate the Facility and provided that each such Seller’s Representative is advised of the confidential nature of such Confidential Information and agrees to be bound by provisions consistent with the provisions of the Agreement or is bound by professional obligations of confidentiality;

 

  (vii)

is disclosed by Buyer to Owner, Owner’s Affiliates and each of their agents, advisors, employees, consultants, contractors, officers, directors, representatives, existing or potential investors, Lenders and existing or potential offtakers (and their respective consultants, advisors and agents) (collectively, the “Buyer’s Representatives”) to the extent necessary to evaluate the Facility and provided that each such Buyer’s Representative is advised of the confidential nature of such Confidential Information and agrees to be bound by provisions consistent with the provisions of the Agreement or is bound by professional obligations of confidentiality; or

 

  (viii)

is disclosed by Buyer or Owner to any Governmental Authority in connection with the Facility.

 

A-57


22.2

Restrictions on Use

Receiving Party agrees:

 

  (a)

to use the Confidential Information only as permitted under the Agreement;

 

  (b)

to take reasonable measures to prevent disclosure of the Confidential Information, except as permitted under the Agreement; and

 

  (c)

not to disclose the Confidential Information to any Person other than its Representatives.

Any Confidential Information disclosed or revealed by the Disclosing Party shall remain the Disclosing Party’s property. Receiving Party agrees to obtain a commitment from any recipient of Confidential Information to comply with the terms of this Clause 22. Confidential Information shall not be reproduced without Disclosing Party’s written consent, and upon expiration or termination of the Agreement, the Receiving Party shall return to the Disclosing Party all Confidential Information in its possession or control, except to the extent that the Agreement entitles Receiving Party to retain the Confidential Information; provided, however, that the return of such Confidential Information shall not affect the license rights granted to Buyer pursuant to Clause 18.

 

22.3

Disclosure

If Receiving Party or any of its Affiliates or Representatives is required to disclose any Confidential Information pursuant to Clause 22.1 (iv), the Receiving Party agrees to provide Disclosing Party with prompt written notice to permit Disclosing Party to seek an appropriate protective order or agency decision or to waive compliance by Receiving Party with the provisions of this Clause 22. In the event that efforts to secure confidential treatment are unsuccessful, Receiving Party may, to the extent lawful, revise the Confidential Information to make it non-proprietary or to minimize the loss of its proprietary value.

 

22.4

No License

Nothing in Clause 22 grants Receiving Party any license to any invention, patent, trademark or copyright now or later owned or controlled by Disclosing Party.

 

A-58


22.5

Available Remedies

Each Party acknowledges that money damages would not be a sufficient remedy for a breach of this Clause 22. The Parties acknowledge that any violation of this Clause 22 by the Receiving Party may cause the Disclosing Party irreparable harm that could not be fully remedied by monetary damages. Accordingly, if it appears that the Receiving Party has disclosed (or has threatened to disclose) Confidential Information in violation of the Agreement, the Disclosing Party shall have the right, in addition to, and not in lieu of, monetary damages or any other legal or equitable remedy available to it, to seek injunctive or other equitable relief from a court of competent jurisdiction, without the necessity of proving damages or posting any bond, as may be necessary to prevent any such violation.

 

22.6

No Public Announcements

Neither Party shall make any public announcement about the Agreement or related documents, including its existence, without prior written approval of the other Party.

 

22.7

Survival

As to any individual item of Confidential Information, the restrictions of this Clause 22 shall expire upon the earlier of five (5) years following the date of disclosure or three (3) years following termination or expiration of the Agreement, except with respect to Confidential Information that the Disclosing Party protects as a trade secret, for which the obligations set forth in this Clause 22 shall remain in effect as long as such Confidential Information remains a trade secret.

 

23.

INSURANCE

 

23.1.

Seller Coverage Requirements.

Seller shall secure, pay for, and provide, at no additional cost or expense to Buyer or Owner, the following insurance coverages during the term of the Agreement:

(a) Workers’ Compensation Insurance with statutory limits in accordance with all applicable state, federal and maritime laws, and Employer’s Liability Insurance with minimum limits of $[***] per accident/occurrence for bodily injury per accident, each employee for disease. No “alternative” forms of coverage will be permitted. If optional under state legal requirements, insurance must cover all employees regardless.

(b) Commercial General Liability Insurance with minimum limits of $[***] combined single limit per occurrence and $[***] in the aggregate, including, but not limited to, coverage for bodily injury liability, property damage liability, products liability including completed operations, personal/advertising injury liability, and sudden and accidental pollution. Buyer and Owner must be named as additional insured.

(c) Automobile Liability Insurance with minimum limits of $[***] combined single limit per accident/occurrence for bodily injury liability and property damage liability, including, but not limited to, coverage for all owned, hired and non-owned vehicles or automotive equipment used by or for Seller and including coverage for contractual liability for those liabilities assumed by the Contractor herein.

 

A-59


(d) Umbrella or Excess Liability Insurance with minimum limits of $[***] per accident/occurrence and in the aggregate in excess of the primary liability coverage and limits contained herein (except Workers’ Compensation Insurance, Property Insurance, and Professional Liability Insurance). This excess coverage shall be no less restrictive than the scope of the coverage afforded by the primary coverage outlined herein and shall have the same inception and expiration dates as Commercial General Liability Insurance.

(e) Professional Liability Insurance, with minimum limits of $[***] combined single limit per occurrence and in the annual aggregate, covering liability stemming from errors or omissions or rendering or failing to render any professional services as required under the Agreement and, as such insurance is provided on a “claims made” basis, (1) with a retroactive date no later than the commencement date of services to be performed under the Agreement, and (2) this insurance is to remain in force or be maintained for at least three years following the completion of services under the Agreement.

(f) Cyber Liability Insurance with minimum limits of $[***] per occurrence and in the aggregate, coverage including, but not be limited to, infringement of intellectual property liability such as copyright, trademark, trade dress, invasion of privacy violations, information theft, damage to or destruction of electronic information, release of private information, alteration of data, extortion and network security. Coverage shall also include breach response costs and regulatory fines and penalties, as well as credit monitoring expenses with limits sufficient to respond to these obligations.

(g) Marine Liability Insurance for all vessels owned, operated, chartered, or brokered by or for Seller in connection with its work or services under the Agreement, Seller shall carry or require the owner or operator of such vessels to carry:

 

  i.

Hull Insurance for replacement cost value of each vessel.

 

  ii.

Protection and Indemnity Insurance with minimum limits of $[***] combined single limit per occurrence to cover liabilities arising out of the ownership, operation and use of any vessel including, but not limited to, coverage for contractual liability for those liabilities assumed by Seller herein, including coverage for crew and personnel on such vessels, with no exclusion for activities arising from the use of remote operated vehicles and submarines and diving operations (if these operations are to be performed under the Agreement), and including Collision and Tower’s Liability, Cargo Legal Liability (to the extent applicable), and coverage for liabilities for the removal of wreck or debris as compulsory under statute or where such wreck or debris interferes with the operations of Owner or third parties. Insurers shall waive any right to limit liability to the value of the vessel, but only with respect to indemnitees, only to the extent of the liabilities assumed, and, to the extent of the liabilities assumed, the policies (including any excess policies) shall be endorsed to provide full coverage to indemnitees, as additional insured, without regard to whether liability has

 

A-60


  been incurred “as owner” of the vessel and the phrase “as owner of vessel named herein” and all similar phrases purporting to limit the insurer’s liability to that of an owner shall be deleted. This insurance shall include coverage for pollution and cleanup liability on a sudden and accidental basis and, where applicable, insurance shall include coverage as provided under the latest Form SP-23 and must satisfy minimum coverage limit requirements under applicable law and include coverage for crew and personnel on such vessels, with no exclusion for activities arising from the use of remote operated vehicles and submarines and diving operations (if these operations are to be performed under the Agreement).

 

  iii.

Charterer’s Legal Liability Insurance, on a form equivalent to the IG Club United Kingdom Mutual Assurance Association (Bermuda) Ltd. standard form of certificate and/or under their club rules for charterers’ risks, with minimum limits of $[***] combined single limit per occurrence to cover liabilities arising out of operation and use of any time or voyage chartered vessel including coverage for contractual liability for those liabilities assumed by Seller herein.

 

  iv.

The insurance listed in (i), (ii) and (iii) above shall provide that seaworthiness of vessels used to perform services under the Agreement is accepted by insurers (or that insurers shall waive in favor of indemnitees, the vessel owner’s and/or Seller’s warranty of seaworthiness).

(h) To the extent of the liabilities assumed by Seller herein and to the extent permitted by applicable law, all insurance policies obtained by Seller that provide liability or property coverage related to the services or work under the Agreement shall be endorsed to provide that:

 

  i.

Seller’s insurers waive their right of subrogation, excluding Professional Liability, (equitable or by assignment, express or implied, loan receipt or otherwise) against Company.

 

  ii.

Seller’s insurers shall name Buyer, Owner and any other person designated by the Buyer as additional insureds, to the extent allowed by law (except for Workers’ Compensation Insurance, Property Insurance, and Professional Liability Insurance).

 

  iii.

such insurance coverage is primary and non-contributory to any other insurance coverage afforded to Buyer or Owner.

 

  iv.

the policy contains cross-liability coverage as provided under standard ISO forms’ separation of insureds clause.

(i) the inception of the Agreement, annually thereafter, and whenever requested, Seller shall furnish insurance certificates to evidence the insurance required herein. However, receipt of such certificates and endorsements shall not relieve Seller of any insurance obligations herein. Furthermore, receipt of such certificates or failure to object to same shall not be deemed to constitute a waiver of any of the insurance requirements required to be carried by Seller herein. Seller’s insurance shall be carried with

 

A-61


insurance companies satisfactory to Buyer (A.M. Best A- VII or better or equivalent) and either Seller, its insurer, and/or its agent. All self-insured amounts, deductible amounts, premiums, franchise amounts or other charges due with respect to each Seller’s required insurance herein shall be the sole obligation of said Seller. Maintaining the prescribed insurance shall not relieve Seller of any other obligation under the Agreement. Failure of Seller to obtain and maintain the required insurance will constitute a breach of the Agreement and Seller shall be liable for any and all costs, liabilities, damages, and penalties.

 

23.2

Additional Requirements.

(a) All commercial general liability and automobile liability insurance coverage shall be written on an occurrence-based form.

(b) An original certificate of insurance shall be delivered to the Buyer within five (5) Days of the Effective Date, prior to commencement of any work or prior to the payment of any amounts by the Buyer hereunder, whichever occurs first. The certificate of insurance shall evidence insurance coverage at least in the minimum limits, or as may be further increased in connection with the requirements of the Agreement. Seller, its insurer, and/or its agent shall provide Buyer thirty (30) Days advance written notice of non-renewal, cancellation, substantial amendment or alteration of such coverage and ten (10) Days prior written notice to the Buyer by certified mail in the event of nonpayment of the premium. Upon request, the Seller shall provide to Buyer copies of the insurance certificates for Buyer’s internal purpose(s).

(c) Seller acknowledges Seller’s obligation to obtain and maintain appropriate insurance coverages for the benefit of Seller (and Seller’s employees, if any). If Seller fails to comply with the obligations for insurance required herein, Buyer shall have the right, but not the obligation, to purchase such insurance at Seller’s sole cost and expense and shall invoice, withhold payment or back charge Seller for the cost incurred by Buyer to satisfy such obligations. Seller waives any rights to recovery from Buyer for any injuries that Seller (and/or the Seller’s employees) may sustain under the Agreement and that are a result of the negligence of Seller or Seller’s employees. Likewise, Buyer waives any rights to recovery from Seller for any injuries that Buyer (and/or Buyer’s employees) may sustain while performing Buyer’s obligations under the Agreement and that are a result of the negligence of Buyer or Buyer’s employees.

(d) Seller shall comply with the statutory insurance requirements for all jurisdictions in which it operates.

 

23.3

Buyer/Owner Insurance

(a) At no expense to Seller, from and after Financial Closing, Owner shall cause a Builder’s All-Risk insurance policy (“BAR Policy”) to be maintained in a coverage amount sufficient to cover the construction, commissioning, and testing of the Facility at the Site. Seller shall receive a waiver of subrogation to the extent of Buyer’s and Owner’s release and indemnity obligations contained in the Agreement.

 

A-62


24.

CHANGE ORDERS

 

24.1

Buyer Change Order

Buyer may, at any time, by written notice to Seller, request an addition to, or deletion from, or other changes in obligations of Seller under Appendix C (Scope of Supply & Project Schedule) and/or items and Deliverables that are to be provided by Seller hereunder, including alterations to the Liquefaction Train System schedule or scope. Seller shall review and reasonably consider such requested change and shall make a written response concerning such change to Buyer within ten (10) Days after receiving such request from Buyer to confirm if Seller will pursue cost and schedule analysis. Within twenty (20) Days of the requested change Seller, will provide a written response to include Seller’s estimated lump-sum fixed cost associated with such requested change together with the estimated number of hours, average hourly rates and material quantities required to carry out such change. If the Parties agree upon such change, the Parties shall set forth the agreed-upon change in a written change order signed by all Parties in the form of Appendix I (a “Change Order”). Each Change Order shall constitute a final accord, satisfaction and settlement of all matters covered therein.

 

24.2

Seller Change Order

To the extent that (a) Seller experiences a Force Majeure Event or (b) a suspension is requested by Buyer in accordance with Clause 29.3, or (c) other circumstances occur which specifically entitle Seller to request a Change Order under the Agreement, if Seller desires to request an equitable adjustment to the Project Schedule and/or Contract Price, Seller shall give Buyer notice within fifteen (15) Days after Seller knows of the occurrence of the event or circumstances giving rise to such request. Within fifteen (15) Days after the delivery of such notice, Seller shall provide Buyer with a written notice setting forth the reasons why Seller believes the Project Schedule or Contract Price should be adjusted and the requested adjustment to the Project Schedule or Contract Price, such written response to include Seller’s estimated lump-sum fixed cost associated with such requested change together with the estimated number of hours and material quantities required to carry out such change. If Buyer does not agree with such requested adjustment, then Buyer shall notify Seller and such disagreement shall be resolved pursuant to the procedures set forth in Clause 20. If Buyer accepts any such requested adjustment to the Project Schedule or Contract Price, a Change Order shall be executed by the Parties and the Project Schedule or Contract Price shall be adjusted in accordance with the terms of such Change Order.

 

24.3

No Interruption of Performance

Except insofar as a Change Order was to specifically modify one or more provisions or conditions of the Agreement, all other provisions and conditions of the Agreement shall remain unaffected. No Change Order shall be deemed issued, or agreed upon, due to a course of dealing or course of the performance of any obligations hereunder, including the performance of any obligations pursuant to any other Change Order, individually or collectively. Seller shall not commence to perform, or perform, any obligations constituting a change from the obligations hereunder, and Buyer shall have no liability to Seller for any such obligations performed, unless Seller and Buyer have executed a Change

 

A-63


Order. Seller shall not suspend, in whole or in part, performance of the Agreement during any dispute over any Change Order or a request for a Change Order unless directed to do so by Buyer, provided that Seller shall not be obligated to proceed with a disputed requested change or a disputed item under a Change Order, until such dispute is resolved, unless (a) such disputed requested change(s) or disputed item(s) (i) have an aggregate value of less than [***] or (ii) is required to address health and safety or environmental issues or (b) Seller elects, at its discretion, to proceed with such disputed requested change or disputed item while the dispute is still pending, provided, further, that, in each such case, Seller shall proceed, without waiving any rights with respect to such disputed requested change or disputed item.

 

25.

PERFORMANCE GUARANTEES, PERFORMANCE TESTS AND PERFORMANCE LIQUIDATED DAMAGES

 

25.1

Performance Guarantees

Seller guarantees to Buyer that the following Performance Guarantees shall be satisfied in accordance with Appendix F (Performance Tests):

 

  (a)

the LNG production capacity (measured in MTPA) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be equal to or greater than the Liquefaction Train Production Capacity Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train;

 

  (b)

the LNG production capacity (measured in lbs/hr) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be equal to or greater than the Liquefaction Train System Production Capacity Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date;

 

  (c)

(i) the minimum performance guarantee with respect to power demand (measured in kWh/Tonne) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train Power Demand Minimum Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train; and

(ii) the full performance guarantee with respect to power demand (measured in kWh/Tonne) for each individual Liquefaction Train, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train Power Demand Performance Guarantee on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train;

 

A-64


  (d)

(i) the minimum performance guarantee with respect to power demand (measured in kWh/Tonne) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train System Power Demand Minimum Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date; and

(ii) the full performance guarantee with respect to power demand (measured in kWh/Tonne) for the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Liquefaction Train System Power Demand Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date;

 

  (e)

the full performance guarantee with respect to any loss in Mixed Refrigerant (measured in standard liters/minute) for the Liquefaction Train System, as measured and adjusted in accordance with Appendix F (Performance Tests), shall be less than or equal to the Refrigerant Losses Performance Guarantee prior to shipment from the manufacturing facility;

 

  (f)

the quality of the LNG produced by the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, as measured and adjusted in accordance with Appendix F (Performance Tests), shall satisfy the LNG Quality Performance Guarantee, on or before the Guaranteed Liquefaction Train System Substantial Completion Date; and

 

  (g)

The Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, will run at the required capacity to meet Facility demand over a [***] hour continuous test period with [***] equivalent availability factor that accounts for any capacity de-ratings during the test period (the “Reliability Guarantee”). Seller shall have a maximum of [***] test periods allotted to satisfy the Reliability Guarantee before a change of equipment or software is required. The Performance Test for the Reliability Guarantee will be run concurrently with tests in Clause 25.1(b).

 

25.2

Performance Tests

Seller shall conduct in accordance with Appendix F (Performance Tests) (a) the Liquefaction Train Performance Tests for an individual Liquefaction Train only after such Liquefaction Train has achieved Ready for Test and (b) the Liquefaction Train System Performance Tests only after the Liquefaction Train System has achieved Ready for Test. Seller shall conduct the Performance Tests for each of the Liquefaction Trains, individually, and the Liquefaction Train System, in its entirety, with all of the Liquefaction Trains operating simultaneously, under the conditions and in strict accordance with the requirements set forth in Appendix F (Performance Tests). If (A) the Liquefaction Train

 

A-65


Performance Tests of an individual Liquefaction Train demonstrate that the Liquefaction Train Performance Guarantees for such Liquefaction Train System have been achieved or (B) the Liquefaction Train System Performance Tests demonstrate that the Liquefaction Train System Performance Guarantees have been achieved, then Seller shall provide Buyer with written notice of such occurrence and shall provide Buyer with a test report, together with supporting documentation, demonstrating the achievement of the applicable Performance Guarantees within ten (10) Days of the date of the completion of such Performance Tests and upon receipt of such documentation Buyer shall, within ten (10) Days, either (A) confirm in writing to Seller the successful completion of the Liquefaction Train Performance Tests or the Liquefaction Train System Performance Tests or (B) provide written notice to Seller of why Buyer disagrees that the Liquefaction Train Performance Guarantees or the Liquefaction Train System Performance Guarantees have been achieved. If any Performance Test indicates that an individual Liquefaction Train or the Liquefaction Train System fails to achieve any Performance Guarantee for reasons attributable to Seller, its Affiliates or Subcontractors, then Seller shall, at its own cost and expense, take appropriate corrective action and Seller shall thereafter reperform the Performance Test.

Seller’s obligation to meet the Liquefaction Train Performance Guarantees under this Clause 25 shall be satisfied when (i) all the Liquefaction Train Performance Tests have been completed, and (ii) either (1) such tests demonstrate that all Liquefaction Train Performance Guarantees are met or (2) such tests demonstrate that the Liquefaction Train Power Demand Minimum Performance Guarantee is met and Seller has paid all payable liquidated damages for the Liquefaction Train Performance Guarantees that are not met.

Seller’s obligation to meet the Liquefaction Train System Performance Guarantees under this Clause 25 shall be satisfied when (i) all the Liquefaction Train System Performance Tests have been completed, and (ii) either (1) such tests demonstrate that all Liquefaction Train System Performance Guarantees are met or (2) such tests demonstrate that the Liquefaction Train Power Demand Minimum Performance Guarantee and the Refrigerant Losses Performance Guarantee are met and Seller has paid all payable liquidated damages for the Liquefaction Train System Performance Guarantees that are not met.

At all times during start-up, testing and commissioning of the Liquefaction Train System, Owner may, at no expense to Seller, arrange for the disposition of the Facility’s LNG. Owner shall have all right, title and interest to all LNG produced by the Facility and all of the proceeds from the sale thereof.

 

25.3

Performance Liquidated Damages and Performance Delay Liquidated Damages

(a) Performance Liquidated Damages

(i) If Seller achieves the Liquefaction Train Power Demand Minimum Performance Guarantee but fails to achieve the Liquefaction Train Power Demand Performance Guarantee for a Liquefaction Train, then Seller shall pay to Buyer [***] Dollars [***] for each kWh/Tonne of LNG produced above the Liquefaction Train Power Demand Performance Guarantee (the “Liquefaction Train Power Demand Liquidated Damages”).

 

A-66


  (ii)

If Seller achieves the Liquefaction Train System Power Demand Minimum Performance Guarantee but fails to achieve the Liquefaction Train System Power Demand Performance Guarantee, then Seller shall pay to Buyer [***] Dollars [***] for each kWh/Tonne of LNG produced above the Liquefaction Train System Power Demand Performance Guarantee (the “Liquefaction Train System Power Demand Liquidated Damages”).

 

  (iii)

The total amount of Performance Liquidated Damages payable by Seller to Buyer shall not exceed the Performance Liquidated Damages Cap and the total amount of Liquidated Damages payable by Seller to Buyer shall not exceed the Liquidated Damages Cap. Once Seller has accrued (i) Performance Liquidated Damages in amount equal to the Performance Liquidated Damages Cap or (ii) Liquidated Damages in amount equal to the Liquidated Damages Cap, [***].

 

  (iv)

The assessment of Liquefaction Train Power Demand Liquidated Damages will not apply concurrently with Liquefaction Train System Power Demand Liquidated Damages.

(b) Performance Delay Liquidated Damages

 

  (i)

If Seller fails to achieve the Liquefaction Train Production Capacity Performance Guarantee for a Liquefaction Train on or before the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train, then Seller shall pay to Buyer an amount equal to: (x) in respect of the first [***] Liquefaction Trains to be performance tested, (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] per Day for each Day of such delay for the next [***]; and (y) in respect of the subsequent [***] Liquefaction Trains to be performance tested, (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] Dollars ([***]) per Day for each Day of such delay for the next [***] (the “Liquefaction Train Production Capacity Liquidated Damages”).

 

  (ii)

If Seller fails to achieve either the Liquefaction Train System Production Capacity Performance Guarantee, or the LNG Quality Performance Guarantee on or before the Guaranteed Liquefaction Train System Substantial Completion Date, then Seller shall pay to Buyer an amount equal to (1) for each of the first [***] of delay, the amount in Dollars set forth opposite such Day on Appendix L (Liquidated Damage Amounts); and (2) thereafter, [***] Dollars ([***]) per Day for each Day of such delay for the next [***] (the “Liquefaction Train System Production Capacity Liquidated Damages” or the “LNG Quality Liquidated Damages”, as applicable).

 

A-67


  (iii)

The aggregate amount of Performance Delay Liquidated Damages payable by Seller to Buyer for each Liquefaction Train shall not exceed the applicable Performance Delay Liquidated Damages Cap. The aggregate amount of Liquefaction Train System Production Capacity Liquidated Damages and LNG Quality Liquidated Damages payable shall not exceed, in the aggregate, the Liquefaction Train System Performance Delay Liquidated Damages Cap. Once Seller has accrued (i) Performance Delay Liquidated Damages in amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (ii) Liquidated Damages in amount equal to the Liquidated Damages Cap, [***].

 

  (c)

Buyer shall invoice Seller on a monthly basis for any amounts due for Performance Liquidated Damages and Performance Delay Liquidated Damages. Payment of any Performance Liquidated Damages and Performance Delay Liquidated Damages by Seller shall occur within ten (10) Business Days following the date Buyer submits to Seller an invoice therefore. Buyer and Seller agree that the amount of Performance Liquidated Damages and Performance Delay Liquidated Damages are reasonable in light of the anticipated harm caused by the breach of duty related thereto and the difficulties of proof of loss and inconvenience or non-feasibility of obtaining any adequate remedy with respect to the actual level of damages Buyer is likely to suffer in the event that Seller fails to achieve the (i) Liquefaction Train Power Demand Performance Guarantee, (ii) Liquefaction Train System Power Demand Performance Guarantee, or (iii)(A) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (B) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, and the Parties are estopped from contesting the validity or enforceability of such liquidated damages. Except as provided in Clause 28.1 and Clause 28.3, the payment of Performance Delay Liquidated Damages shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for Seller’s failure to achieve (w) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (x) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date. Except as provided in Clause 28.1 and Clause 28.3, the payment of Performance Liquidated Damages shall be Buyer’s sole and exclusive remedy and Seller’s sole and exclusive liability for Seller’s failure to achieve (y) the Liquefaction Train Power Demand Performance Guarantee or (z) the Liquefaction Train System Power Demand Performance Guarantee. In the event the Performance Liquidated Damages or

 

A-68


  Performance Delay Liquidated Damages provisions are found for any reason to be void, invalid or otherwise inoperative so as to disentitle Buyer from claiming and recovering Performance Liquidated Damages or Performance Delay Liquidated Damages from Seller, Buyer shall, in addition to the remedies set forth below in Clause 25.4, be entitled to claim against Seller and recover for damages for Seller’s failure to achieve (1) the Liquefaction Train Performance Guarantees for a Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train, (2) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, (3) Liquefaction Train Power Demand Performance Guarantee or (4) Liquefaction Train System Power Demand Performance Guarantee; provided that such damages shall not exceed, in the case of Clauses (1) and (2), the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, and, in the case of Clauses (3) and (4), the Performance Liquidated Damages Cap.

 

25.4

Buyer Remedies

If Seller has accrued an aggregate amount of (i) Performance Liquidated Damages in an amount equal to the Performance Liquidated Damages Cap, (ii) Performance Delay Liquidated Damages in an amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (iii) Liquidated Damages in an amount equal to the Liquidated Damages Cap, then Buyer may by notice to Seller, at Buyer’s sole discretion, either:

 

  (a)

[***]

 

  (b)

[***]

 

25.5

Performance Guarantees [***]

 

A-69


Seller acknowledges and agrees that its Unconditional Performance Obligation is [***].

 

26.

ACCESS AFTER DELIVERY

For the sole purpose of (and to the extent necessary for) performing its obligations under the Agreement regarding the remedying of Defects or guaranteed performance, Seller may request Buyer (who shall not unreasonably withhold its consent) to have the right of access to all parts of the Liquefaction Train System(s). Such access shall only be granted during normal working hours and will be limited to the duly authorized representatives of Seller, provided that (a) Seller shall, and shall cause its authorized agents, employees and inspectors to, at all times comply with Buyer’s safety and security requirements when present at the Site and (b) Seller shall not, and shall cause its authorized agents, employees and inspectors not to, interfere with the operation of any Liquefaction Train System or the Facility. Seller understands and acknowledges that the Liquefaction Trains will commence commercial operations prior to the Substantial Completion of the Facility.

 

27.

QUALITY ASSURANCE AND QUALITY CONTROL

The quality control exercised by Seller in its manufacture of the Liquefaction Train System shall be in accordance with the standards set forth in Appendix E (Quality Assurance and Quality Control).

 

28.

EVENTS OF DEFAULT; REMEDIES

 

28.1

Events of Default for Seller

Each of the following events constitutes an Event of Default of Seller under the Agreement:

 

  (a)

Seller fails to make when due any payment (other than amounts disputed in good faith) due and owing under the Agreement and such failure is not cured within ten (10) Working Days after Buyer notifies Seller of such failure;

 

A-70


  (b)

Seller is in material breach of its obligations under the Agreement (other than an obligation to make payment or an obligation that is otherwise specifically set forth in this Clause 28.1 as a separate Event of Default) and such material breach is not remedied within thirty (30) Days after Buyer notifies Seller of such material breach, which notice sets forth in reasonable detail the nature of such material breach, provided that if such material breach is not reasonably capable of being remedied within the thirty (30) Day remedy period specified above but is reasonably capable of being remedied, Seller shall have an additional sixty (60) Day remedy period to remedy such material breach, so long as Seller promptly commences and thereafter diligently pursues such remedy;

 

  (c)

Seller fails to establish or maintain the credit support required under Clause 7.9, and such breach is not cured within ten (10) Working Days after written notice of such breach from Buyer;

 

  (d)

Any representation or warranty made by Seller in Clause 32.2 is not true in all material respects as of the date made and such inaccuracy is not cured within thirty (30) Days after Buyer notifies Seller of such inaccuracy, which notice sets forth in reasonable detail the nature of the inaccuracy;

 

  (e)

A Bankruptcy Event occurs with respect to Seller;

 

  (f)

Seller assigns the Agreement, except as described in Clause 4.1;

 

  (g)

If Seller has accrued an aggregate amount of Delivery Delay Liquidated Damages in an amount equal to the Delivery Delay Liquidated Damages Cap or Aggregate Delivery Delay Liquidated Damages Cap, as applicable, and has not delivered all of the Liquefaction Trains (in their entirety) to the Delivery Point; and

 

  (h)

If Seller has accrued an aggregate amount of (i) Performance Liquidated Damages in an amount equal to the Performance Liquidated Damages Cap, (ii) Performance Delay Liquidated Damages in an amount equal to the Performance Delay Liquidated Damages Cap or Aggregate Performance Delay Liquidated Damages Cap, as applicable, or (iii) Liquidated Damages in an amount equal to the Liquidated Damages Cap and Seller has failed to achieve (A) the Liquefaction Train Performance Guarantees for any Liquefaction Train by the Guaranteed Liquefaction Train Substantial Completion Date for such Liquefaction Train or (B) the Liquefaction Train System Performance Guarantees by the Guaranteed Liquefaction Train System Substantial Completion Date, (C) Liquefaction Train Power Demand Performance Guarantee or (D) Liquefaction Train System Power Demand Performance Guarantee.

If an Event of Default with respect to Seller has occurred, Buyer will have the right, but not the obligation, at any time when such Event of Default is continuing, to designate by notice to Seller a date for terminating the Agreement that will be no earlier than thirty (30) Days after the notice is deemed delivered. Upon the date designated as the termination date by Buyer as a result of an Event of Default of Seller, Buyer shall suspend any further payment to Seller under the Agreement.

 

A-71


28.2

Events of Default for Buyer

Each of the following events constitutes an Event of Default of Buyer under the Agreement:

 

  (a)

Buyer fails to make when due any payment (other than amounts disputed in good faith) due and owing under the Agreement and such failure is not cured within ten (10) Working Days after Seller notifies Buyer of such failure;

 

  (b)

Buyer is in material breach of its obligations under the Agreement (other than an obligation to make payment or an obligation that is otherwise specifically set forth in this Clause 28.2 as a separate Event of Default) and such material breach is not remedied within thirty (30) Days after Seller notifies Buyer of such material breach, or if such material breach cannot be reasonably remedied within such thirty (30) Day period, Buyer has not commenced to cure such material breach within thirty (30) Days of notice from Seller, which notice sets forth in reasonable detail the nature of such material breach, provided that if such material breach is not reasonably capable of being remedied within the thirty (30) Day remedy period specified above but is reasonably capable of being remedied, Buyer shall have an additional sixty (60) Day remedy period to remedy such material breach, so long as Buyer promptly commences and thereafter diligently pursues such remedy;

 

  (c)

Buyer fails to establish or maintain the credit support as required by Clause 7.8 and such breach is not cured within ten (10) Working Days after written notice of such breach from Seller;

 

  (d)

Any representation or warranty made by Buyer in Clause 32.1 is not true in all material respects as of the date made and such inaccuracy is not cured within thirty (30) Days after Seller notifies Buyer of such inaccuracy, which notice sets forth in reasonable detail the nature of the inaccuracy;

 

  (e)

A Bankruptcy Event occurs with respect to Buyer; and

 

  (f)

Buyer assigns the Agreement, except as described in Clause 4.1.

If an Event of Default with respect to Buyer has occurred, Seller will have the right, but not the obligation, at any time when such Event of Default is continuing, to designate by notice to Buyer a date for terminating the Agreement that will be no earlier than thirty (30) Days after the notice is deemed delivered. Upon the date designated as the termination date by Seller as a result of an Event of Default of Buyer, Seller shall (i) terminate performance of its obligations under the Agreement; and (ii) invoice Buyer in connection with any obligations performed under the Agreement for which Seller has not received payment by Buyer.

 

A-72


28.3

Remedies

Upon any termination of the Agreement (including by Buyer under Clause 6.5(b) or Clause 29.1), Seller shall deliver to Buyer the portions of the Liquefaction Train System for which Seller has received payment and which have not been delivered to the Delivery Point. Except where exclusive and/or sole remedies are expressly provided herein, (a) remedies available to each Party under the Agreement are cumulative and (b) whether or not the Agreement is terminated in accordance with this Clause 28, each Party may assert any claims under the Agreement, at law or in equity against the other Party for damages incurred by such Party resulting from any breach of, or default under, the Agreement by the other Party; but the Parties agree that such remedies and claims for damages incurred by such Party resulting from any breach of, or default under, the Agreement by the other Party are always subject to the (i) limitations and exclusions of liability and (ii) dispute resolution provisions provided for in the Agreement; provided, further, that the Delivery Delay Liquidated Damages Cap, Aggregate Delivery Delay Liquidated Damages Cap, the Aggregate Performance Delay Liquidated Damages Cap, the Performance Delay Liquidated Damages Cap, the Liquefaction Train System Performance Delay Liquidated Damages Cap, the Performance Liquidated Damages Cap and the Liquidated Damages Cap shall not be construed to limit either Party’s liability hereunder upon a termination of the Agreement. Each Party agrees that it has a duty to mitigate Costs and covenants that it will use commercially reasonable efforts to minimize any Costs, including termination Costs that it may incur as a result of the other Party’s performance or non-performance hereof. Neither the termination nor expiration of the Agreement will relieve either Party of: (i) any undischarged liability of such Party in respect of the period prior to such termination or expiration (including for unpaid amounts owing under the Agreement in respect of the period prior to such termination or expiration, including payments due as a result of events occurring prior to such termination or expiration); or (ii) any liability for breach by such Party of the Agreement.

 

29.

TERMINATION AND SUSPENSION

 

29.1

Termination by Buyer

Buyer may at any time terminate the Agreement for its convenience by giving Seller [***] written notice of termination, but subject to payment of the Termination Fees in accordance with Clause 29.2. The Agreement shall terminate with effect from the date indicated in such notice.

 

29.2

Termination Fee

In the event of a termination of the Agreement by Buyer under Clause 29.1, Buyer shall pay to Seller the applicable termination payment, as determined in accordance with Appendix B (Pricing; Payment Terms & Cancellation Schedule) (the “Termination Fee”), provided that under no circumstances shall the Termination Fee exceed the applicable maximum Termination Fee set forth in the table in Appendix B (Pricing; Payment Terms & Cancellation Schedule) (the “Maximum Termination Fee”). The Termination Fee, if any, shall be paid within thirty (30) Days from Seller’s invoice therefor. The Termination Fee, if any, shall be Seller’s sole and exclusive remedy and Buyer’s sole and exclusive liability for a termination of the Agreement by Buyer for Buyer’s convenience. BUYER AND SELLER AGREE THAT THE TERMINATION FEE REPRESENTS AN ACCURATE, REASONABLE AND CONSERVATIVE ESTIMATE OF THE ACTUAL LEVEL OF DAMAGES SELLER IS LIKELY TO SUFFER IN THE EVENT OF SUCH TERMINATION.

 

A-73


29.3

Order to Suspend Execution of the Agreement

 

  (a)

Buyer may at any time, upon thirty (30) Days’ prior written notice, instruct Seller to suspend the performance of Seller’s obligations under the Agreement or any portion thereof for such time and in such manner as Buyer may reasonably consider necessary. Upon receiving any such notice of suspension, Seller shall: (i) properly protect and secure the Liquefaction Train System against any deterioration, loss or damage, as considered necessary or required by Buyer; (ii) place no further purchase orders or subcontracts for materials, services or facilities with respect to the suspended performance; (iii) promptly make every reasonable effort to obtain suspension, with terms satisfactory to Buyer of all subcontracts with all Subcontractors to the extent they related to the suspended performance; and (iv) take any other reasonable steps to minimize costs and expenses associated with such suspension.

 

  (b)

Any Costs reasonably incurred and properly documented by Seller (including, but not limited to, demobilization and/or remobilization, storage, preservation, inspection, related labor and any other costs due to such suspension) in giving effect to Buyer’s suspension instructions under this Clause 29.3, shall be borne and paid by Buyer, or, unless such suspension is (i) necessary by reason of a breach or Event of Default on the part of Seller or (ii) due to a Force Majeure Event.

 

  (c)

If Buyer is in breach of its obligation to timely pay undisputed amounts owed to Seller under the Agreement, Seller may suspend immediately upon written notice to Buyer, without penalty and without further proof or establishment of cause, the performance of Seller’s obligations until such undisputed payment is made by Buyer. Seller shall be entitled to request a Change Order for an equitable adjustment of the Project Schedule to the extent that such Seller suspension adversely affects the delivery of any Liquefaction Train in accordance with the Project Schedule. Any Costs reasonably incurred and properly documented by Seller in accordance with such suspension (including storage, demobilization and re-mobilization costs) shall be payable by Buyer within thirty (30) Days of receipt of Seller’s invoices, provided Seller shall exercise commercially reasonable efforts to mitigate and minimize such Costs.

 

29.4

Resumption of Works

At any time after a suspension under Clause 29.3, Buyer may give written notice to Seller to proceed with the delivery of the Liquefaction Trains and/or with the execution of all or part of the Agreement suspended under this Clause 29. Seller will be entitled to a Change Order to equitably adjust the Contract Price and the Project Schedule prior to resuming performance.

 

A-74


29.5

Prolonged Suspension

If the performance of Seller’s obligations under the Agreement or any portion thereof is suspended pursuant to Clause 29.3 for more than [***] in the aggregate during the term of the Agreement, then Seller may serve notice in writing to Buyer requesting permission to proceed with the Agreement or the portion in regard to which progress is suspended. If such permission to proceed is not granted by Buyer within [***] of Buyer’s receipt of such notice, either Party may, by a further prior written notice to the other Party, elect to terminate the Agreement. Seller shall transfer or assign to Buyer, title in the part of the Liquefaction Train System for which payment has been received in full as of the date of any termination of the Agreement. This Clause 29.5 shall not apply if the suspension was (i) necessary by reason of some material default on the part of Seller or (ii) due to a Force Majeure Event.

 

30.

GENERAL CLAUSES

 

30.1

No Third Party Beneficiary

The Parties expressly agree that Owner shall be a third party beneficiary of the Agreement entitled, in its own name, in the name of Buyer or in the name of any assignee of Buyer to enforce the Agreement against Seller (subject to such enforcement being subject to all the limitations, exclusions, remedies and defenses provided to Seller under the Agreement). Except as provided in the foregoing sentence with respect to Owner and in Clause 18.8, Clause 19.2 and Clause 19.3 with respect to the Buyer Parties and the Seller Parties, the provisions of the Agreement are for the benefit of the Parties hereto and not for any other third party. The Agreement shall be binding upon and inure to the benefit of each of the Parties and their respective successors and permitted assigns.

 

30.2

Severability

Should a determination be made by a court of competent jurisdiction that any provision of the Agreement is illegal, invalid or otherwise unenforceable, the same shall not affect the other terms or provisions of the Agreement, but such provisions shall be deemed modified to the extent necessary in the court’s opinion to render such term or provision enforceable, and the rights and obligations of the Parties shall be construed and enforced accordingly, preserving to the fullest extent possible the intent and agreements of the Parties set forth herein.

 

30.3

Counterparts

The Agreement may be executed in one or more counterparts, each of which shall be deemed an original, but all of which taken together shall constitute one and the same instrument. Signatures may be delivered electronically or by facsimile, and such copies shall be treated as originals for all purposes.

 

A-75


30.4

Attorney Review

The Parties acknowledge that each Party and its attorney have reviewed the Agreement and that any rule of construction to the effect that any ambiguities are to be resolved against the drafting Party, or any similar rule operating against the drafter of an agreement, shall not be applicable to the construction or interpretation of the Agreement.

 

30.5

Time is of the Essence

Time is of the essence in the performance of the Agreement.

 

30.6

No Waiver

The waiver by a Party of a breach of any provision of the Agreement by the other Party shall not be construed as a waiver of any succeeding breach of the same or any other provision, nor shall any delay or omission on the part of a Party to exercise or avail itself of any right, power or privilege that it has, or may have, hereunder operate as a waiver of any right, power or privilege by such Party. Any consent or permission granted under the Agreement shall be effective only in the specific instance and for the specific purpose given.

 

30.7

Survival

Upon termination of the Agreement, the rights and obligations of the Parties hereunder shall terminate, except for: (i) provisions that are indicated herein as surviving and those provisions that by their nature are intended to survive; and (ii) rights and obligations accrued as of the date of termination and in connection therewith.

 

30.8

Relationship to First Phase

The Parties acknowledge and agree that the Initial L TS Purchase Order is an independent agreement between the Parties and, notwithstanding anything contained herein to the contrary, the Agreement shall not be construed to interpret or modify, or otherwise challenge the enforceability of or invalidate the Initial L TS Purchase Order.

 

31.

HAZARDOUS MATERIALS

 

31.1

Hazardous Materials

Seller shall, and shall cause all of its Subcontractors to, comply with all applicable Laws relating to Hazardous Materials. If Seller is performing any of its obligations hereunder at the Site, Seller shall not, nor shall it permit any Subcontractor to, bring, introduce, use or release any Hazardous Material on or at the Site. Seller shall be responsible for the

 

A-76


management, storage, disposal, removal, treatment and/or remediation of any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site. In addition, Seller shall not, and shall cause its Subcontractors to not, take any action or fail to take any action, that may disrupt, release or exacerbate, or render more costly the removal or remediation of, any Hazardous Materials existing on the Site prior to the date Seller commences the performance of its obligations hereunder on the Site. Seller shall indemnify, defend, release and hold harmless the Buyer Parties from any costs, expenses or liability resulting from any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site, to the extent resulting from Seller’s or its Subcontractors’ fault, negligence (in any form) or willful misconduct. Buyer shall indemnify, defend, release and hold harmless the Seller Parties from any costs, expenses or liability resulting from any Hazardous Material use or releases on or at the Site, excluding any Hazardous Materials that Seller or any of its Subcontractors brings, introduces, uses or releases on or at the Site.

 

31.2

Notification

If Seller encounters a condition at the Site involving a Hazardous Material or if Seller or anyone for whom Seller is responsible creates a condition involving a Hazardous Material, Seller shall promptly: (a) secure or otherwise isolate such condition, (b) stop its performance of its obligation hereunder in connection with such condition and in any area affected thereby and not take any action that may disrupt, release or exacerbate any such condition, and (c) verbally notify Buyer (and promptly thereafter confirm such notice of such condition in writing). Seller shall cooperate with and assist Buyer in making the Site available for the taking of necessary remedial steps.

 

32.

REPRESENTATIONS AND WARRANTIES

 

32.1

Buyer Representations and Warranties

Buyer hereby represents and warrants to Seller that as of the Effective Date: (a) Buyer is a limited liability company duly organized, validly existing and in good standing under the laws of its state of organization and has all requisite limited liability company power and authority to own and operate its properties and assets and to carry on its business as now conducted; (b) Buyer is duly qualified and is authorized to transact business and is in good standing as a foreign organization in each jurisdiction in which the failure so to qualify would have a material adverse effect on its ability to perform its obligations under the Agreement; (c) all limited liability company action on its part and on the part of its officers, managers and/or members necessary for the authorization, execution and delivery of the Agreement and the performance by it of all of its obligations hereunder have been taken; (d) it has obtained all governmental approvals or third party approvals required for the performance by it of its obligations under the Agreement; (e) there is no action pending or, to its knowledge, currently threatened against it that seeks to prohibit the transactions contemplated by the Agreement or adversely affect its ability to perform under the Agreement; and (f) the Agreement constitutes the legal, valid and binding obligation of Buyer, enforceable in accordance with its terms (subject to principles of equity, the effect

 

A-77


of bankruptcy, insolvency, reorganization, receivership, moratorium, and other similar laws), and the execution, delivery and performance of the Agreement by Buyer does not and will not, in any material respect, conflict with, violate or cause a breach of any applicable Law, material agreement, contract or instrument to which Buyer is a party or any judgment, order or decree to which Buyer is subject.

 

32.2

Seller Representations and Warranties

Seller hereby represents and warrants to Buyer that as of the Effective Date: (a) Seller is a limited liability company duly organized, validly existing and in good standing under the laws of its state of organization and has all requisite limited liability company power and authority to own and operate its properties and assets and to carry on its business as now conducted; (b) Seller is duly qualified and is authorized to transact business and is in good standing as a foreign organization in each jurisdiction in which the failure so to qualify would have a material adverse effect on its ability to perform its obligations under the Agreement; (c) all limited liability company action on its part and on the part of its officers, managers and/or members necessary for the authorization, execution and delivery of the Agreement and the performance by it of all of its obligations hereunder have been taken; (d) it has obtained all governmental approvals or third party approvals required for the performance by it of its obligations under the Agreement; (e) there is no action pending or, to its knowledge, currently threatened against it that seeks to prohibit the transactions contemplated by the Agreement or adversely affect its ability to perform under the Agreement; (f) the Agreement constitutes the legal, valid and binding obligation of Seller, enforceable in accordance with its terms (subject to principles of equity, the effect of bankruptcy, insolvency, reorganization, receivership, moratorium, and other similar laws), and the execution, delivery and performance of the Agreement by Seller does not and will not, in any material respect, conflict with, violate or cause a breach of any applicable Law, material agreement, contract or instrument to which Seller is a party or any judgment, order or decree to which Seller is subject.

 

33.

FORCE MAJEURE

 

33.1

Force Majeure Event

 

  (a)

Each Party shall not be liable or be considered to be in breach or default of its obligations under the Agreement to the extent that performance of such obligations is delayed or prevented, by a Force Majeure Event. A “Force Majeure Event” means any cause or event, or any combination of any causes or events, that: (i) is unforeseeable; (ii) is beyond the reasonable control and without fault or negligence of the affected Party; (iii) could not have been prevented in whole or in part by the exercise of reasonable care and skill by the affected Party; and (iv) materially impairs or prevents the performance of obligations under the Agreement by the affected Party. Subject to the requirements of the preceding sentence, Force Majeure Events may include, but are not limited to, acts of God or the public enemy, acts (or omissions) of Governmental Authorities, fires, severe weather conditions, earthquakes, strikes or other labor disturbances, floods, war (declared or

 

A-78


  undeclared), armed conflict, acts or threats of terrorism, epidemics (including the pandemic known as COVID-19), civil unrest, riot, delays or interruptions of or by any Governmental Authority of the Country or of any other governments having jurisdiction, embargoes or quarantines. The Parties acknowledge that the Agreement reflects the impact of the COVID-19 epidemic as of the Effective Date. To the extent new adverse circumstances pertaining to the COVID-19 epidemic arise after the Effective Date, each Party shall continue to work in good faith to mitigate any resulting impact, and shall be entitled, if and to the extent applicable, to relief in accordance with this Clause 33.

 

  (b)

For the avoidance of doubt, a Force Majeure Event does not include (except and to the extent that they result directly from a Force Majeure Event), among others: (i) technical failures, normal wear and tear in machinery, or breakdown in equipment; (ii) shortage of parts, materials or other similar circumstances for which Seller may be responsible pursuant to the Agreement; (iii) late or non-delivery of machinery, equipment, materials or spare parts; (iv) a delay or default in the performance of any Subcontractor or supplier, or any other contractor; (v) strike or labor disturbances limited in scope to those solely affecting Seller or any of its Major Subcontractors; and (vi) changes since the date hereof in applicable Laws or their interpretation.

 

33.2

Force Majeure Relief

So long as the affected Party has at all times since the occurrence of the Force Majeure Event complied with the obligations of this Clause 33 and continues to so comply, then:

 

  (a)

the affected Party shall not be liable for any failure or delay in performing its obligations which are affected by the Force Majeure Event under or pursuant to the Agreement during the existence of a Force Majeure Event;

 

  (b)

each Party will bear its Cost caused by the circumstances of the Force Majeure Event; and

 

  (c)

in case of a Force Majeure Event affecting Seller, Buyer shall be released from its payment obligations under the Agreement, other than in respect of any amounts that became due and owing under the Agreement prior to the occurrence of the Force Majeure Event that are unpaid, for the duration of the Force Majeure Event.

If Seller claims a Force Majeure Event, Seller shall be entitled to request a Change Order pursuant to Clause 24, in order to obtain an equitable suspension of performance or extension of time (including an extension of the Project Schedule to the extent compliance thereof is affected) with respect thereto.

 

A-79


33.3

Notice of Force Majeure

If either Party considers that a Force Majeure Event has occurred which may affect performance of its obligations, it shall notify the other Party as soon as possible but within a maximum often (10) Days from the Force Majeure Event occurrence date (or from the date it became aware of the occurrence) giving written particulars of the relevant event and its effect upon its performance under the Agreement and, where known, the expected duration of the failure to perform. If the Party declaring a Force Majeure Event does not notify the other Party within such ten (10) Day period, then any relief provided to the declaring Party under this Clause 33 shall only be available as of the date that such notice was provided to the other Party. As soon as the Force Majeure Event has ended, the Party claiming such Force Majeure Event shall give written notice to the other Party of the precise date of the end of the Force Majeure Event and the extent, with justification, to which it has actually been affected in the performance of its obligations.

 

33.4

Force Majeure Report

Upon the occurrence of any Force Majeure Event, Seller shall use its best efforts to continue to perform its obligations under the Agreement and to minimize the adverse effects of such Force Majeure Event. Seller shall notify Buyer of the steps it proposes to take including any reasonable alternative means to continue the performance of its obligations under the Agreement. Seller shall not take any such steps unless approved by Buyer. In the case of Seller declaring a Force Majeure Event, within twelve (12) Days after giving such notice Seller shall prepare and deliver to Buyer an appraisal report of the effects of the Force Majeure Event (the “Force Majeure Report”). The Force Majeure Report shall:

 

  (a)

specify the Force Majeure Event;

 

  (b)

describe the damage to and/or other effects on the Liquefaction Train System resulting from the Force Majeure Event; and,

 

  (c)

provide a good faith estimate (in each case to the extent applicable in the circumstances) of:

 

  (i)

the time it will take to restore such condition;

 

  (ii)

the effect which the relevant Force Majeure Event is likely to have upon any other contract relating to the Agreement;

 

  (iii)

whether or not, in Seller’s opinion, the completion or continued manufacturing of the Liquefaction Train System is technically viable with the reasons for such opinion; and

 

  (iv)

include all relevant supporting documentation.

In addition to the Force Majeure Report, Buyer may request, and Seller shall promptly provide, such related information pertaining to the Force Majeure Report as may be reasonable.

 

A-80


33.5

Termination for Force Majeure

If circumstances or consequences of a Force Majeure Event have occurred and shall continue for an uninterrupted period of [***] after date of occurrence then, notwithstanding that Seller may by reason thereof have been granted an extension of the Delivery Date, the non-claiming Party shall be entitled to serve upon the Party affected by the Force Majeure Event an additional fifteen (15) Days’ notice to terminate the Agreement. If, at the expiry of such period, the Force Majeure Event is still in effect, the Agreement shall terminate. In the event of a termination of the Agreement due to a Force Majeure Event, the following provisions shall apply:

 

  (a)

neither Party shall have any liability to the other in respect of termination of the Agreement due to a Force Majeure Event, but rights and liabilities which have accrued prior to termination shall survive;

 

  (b)

upon such termination, Seller shall transfer or assign to Buyer, title in the part of the Liquefaction Train System for which payment has been received in full as of the date of the termination of the Agreement under this Clause 33.5; and

 

  (c)

upon such termination, Buyer shall pay to Seller any unpaid amounts due Seller for Payment Milestones completed as of the date of termination.

 

34.

LIMITED RECOURSE

 

  (a)

Except to the extent as otherwise provided in any parent guarantee provided to Seller under the Agreement, in the event of non-performance by Buyer of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (i) any assets or properties of any of the shareholders, members or partners of the Buyer, (ii) any Affiliate of Buyer or (iii) any officers, directors or employees thereof, and no judgment relating to the obligations of Buyer under the Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of Buyer or any other officer, employee or director past, present or future of Buyer or any of its shareholders, members, partners or Affiliates.

 

  (b)

Except to the extent otherwise provided in any parent guarantee provided to Buyer under the Agreement, in the event of non-performance by Seller of its obligations hereunder, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, no recourse shall be had to (i) any assets or properties of any of the shareholders, members or partners of the Seller, (ii) any Affiliate of Seller or (iii) any officers, directors or employees thereof, and no judgment relating to the obligations of Seller under the Agreement or for any claim based thereon or otherwise in respect thereof or related thereto, shall be obtainable by Seller against any shareholder, member, partner or Affiliate of the Seller or any other officer, employee or director past, present or future of the Seller or any of its shareholders, members, partners or Affiliates.

 

A-81


APPENDIXB

PRICING; PAYMENT TERMS & CANCELLATION SCHEDULE

See attached.

 

B-1


APPENDIXB

PRICING, PAYMENT TERMS & CANCELLATION SCHEDULE

Seller shall not issue more than one (1) invoice (or, following the assignment of the Agreement to the EPC Contractor, two (2) invoices) in any calendar month during the term of the Agreement.

Seller shall not be entitled to invoice for a Payment Milestone until such Payment Milestone has been completed, such invoice shall include reasonable documentation of such completion of the Payment Milestone, including the documentation identified in the Payment Milestone Notes below and as may be further defined between Buyer and Seller during the kickoff meeting. Invoices shall include an affidavit setting forth the amounts paid by Seller to any “Major Subcontractors” under the Agreement in a form reasonably acceptable to Buyer and the Lenders.

In addition to the amounts shown in the Payment Milestone in Section I.B., below, Seller shall be permitted to invoice Buyer for the fixed fee of [***] as provided in Clause 7.1 of Appendix A of the Agreement in equal monthly installments in the amount of [***] during the first [***] of the Payment Schedule following the issuance of FNTP.

The Transportation Costs as defined in Clause 7.1 of Appendix A shall not be included in the Aggregate Payment Milestone Cap. Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice for the transportation fixed fee and the Transportation Costs.

Transportation Costs shall be documented by Seller providing to Buyer unredacted copies of purchase orders and other available documentation. Copies of invoices shall be provided as part of the monthly invoice for individual purchase orders or Transportation Costs with a value in excess of $[***]. In all other cases, Facility-specific ERP system reports in Excel format will be submitted with the applicable monthly invoice. Transportation Costs shall be certified by the Project Director as part of the applicable monthly invoice.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to any Cameron Parish sales and use taxes that constitute Buyer Taxes. Any such Cameron Parish sales and use taxes shall be documented by Seller providing the list, value, and delivery date of the delivered equipment.

Concurrently with the monthly invoice described in the first paragraph of this Appendix B, Seller may submit to Buyer a dedicated monthly invoice with respect to the Spare Parts. Spare Parts shall be documented by the Seller providing the list of the delivered spare parts and/or other available documentation to the Seller.

Buyer shall have the right to audit all documentation pertaining to Transportation Costs and taxes on reasonable prior notice to Seller and during normal business hours in order to confirm the accuracy and completeness thereof.

 

B-2


I.

Payment Milestones:

 

  A.

Payment Milestones after Buyer’s issuance of LNTP shall be as indicated in the table below.

 

Type

   Milestone
  

Milestone Description

   Amount
(USD)

[***]

   1    [***]    [***]

[***]

   LI    [***]    [***]

[***]

   2    [***]    [***]

[***]

   3    [***]    [***]

 

  B.

Payment Milestones after Buyer’s issuance of FNTP shall be as indicated in the table below. The “Fixed” Payment Milestones (as indicated below) are one-time events. The “By Train” Payment Milestones (as indicated below) shall occur for each Liquefaction Train.

 

Type

   Milestone
  

Milestone Description

   Amount
(USD)

[***]

   1    [***]    [***]

[***]

   LI    [***]    [***]

 

B-3


Type

   Milestone
  

Milestone Description

   Amount
(USD)
 

[***]

   2    [***]      [***]  

[***]

   3    [***]      [***]  

[***]

   4    [***]      [***]  

[***]

   5    [***]      [***]  

[***]

   6    [***]      [***]  

[***]

   7    [***]      [***]  

[***]

   8    [***]      [***]  

[***]

   9    [***]      [***]  

[***]

   10    [***]      [***]  

[***]

   11    [***]      [***]  

[***]

   12    [***]      [***]  

[***]

   13    [***]      [***]  

[***]

   14    [***]      [***]  

[***]

   15    [***]      [***]  

[***]

   16    [***]      [***]  

 

B-4


Type

   Milestone
No
  

Milestone Description

   Amount
(USD)

[***]

   17    [***]    [***]

[***]

   18    [***]    [***]

[***]

   19    [***]    [***]

[***]

   20    [***]    [***]

[***]

   21    [***]    [***]

[***]

   22    [***]    [***]

[***]

   23    [***]    [***]

[***]

   24    [***]    [***]

[***]

   25    [***]    [***]

[***]

   26    [***]    [***]

 

  

Payment Milestone Notes

1    [***]
2    [***]
3    [***]
4    [***]
5    [***]
6    [***]
7    [***]

 

B-5


  

Payment Milestone Notes

8    [***]
9    [***]
10    [***]
11    [***]

 

B-6


  

Payment Milestone Notes

12    [***]
13    [***]
14    [***]

 

B-7


II.

Aggregate Payment Milestone Cap:

The aggregate amount of all Payment Milestones invoiced by Seller as of each month, including all invoices submitted to Buyer in prior months, shall not exceed the amount of the Aggregate Payment Milestone Cap shown in tables below for such month.

 

  A.

[***]

 

Month after Issuance of LNTP

   Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

  A.

[***]

 

Month after Issuance of LNTP or

FNTP (as applicable)

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-8


Month after Issuance of LNTP or

FNTP (as applicable)

  

Aggregate Payment Milestone Cap (by month)

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-9


III.

Termination Fee:

In the event of termination for convenience by Buyer pursuant to Clause 29.1 of Appendix A or a termination by Buyer or Seller, as applicable, if there is no mutual agreement on extending the time for issuance of FNTP pursuant to Clause 6.6 of Appendix A, then the Termination Fee, if any, payable by Buyer shall be determined as follows:

[***]

where:

[***]

 

Months after issuance of LNTP

or issuance of a Suspension Notice, as

Applicable

   Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-10


4.

If LNTP is issued and FNTP is subsequently issued prior to the termination of the Agreement, the Maximum Termination Fee shall be as follows; provided, however, that if (a) no LNTP is issued but the FNTP is issued or (b) FNTP is issued less than [***] after the issuance of LNTP, in either case, the Maximum Termination Fee set forth in the first [***] in the table below shall be increased by [***].

 

Months after issuance of LNTP or

FNTP or issuance of a Suspension

Notice, as applicable

   Maximum Termination Fee

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

[***]

   [***]

 

B-11


APPENDIX C

SCOPE OF SUPPLY & PROJECT SCHEDULE

[Omitted]

 

C-1


APPENDIX D

GUARANTY AGREEMENT

[Omitted]

 

D-1


APPENDIX E

QUALITY ASSURANCE AND QUALITY CONTROL

[Omitted]

 

E-1


APPENDIX F

PERFORMANCE TESTS

[Omitted]

 

F-1


APPENDIX G

APPROVED SUBCONTRACTORS

[Omitted]

 

G-1


APPENDIX H

FORM OF SELLER PARENT COMPANY GUARANTEE

[Omitted]

 

H-1


APPENDIX I

FORM OF CHANGE ORDER

[Omitted]

 

I-1


APPENDIX J

FORM OF LIEN WAIVERS AND RELEASES

[Omitted]

 

J-1


APPENDIX K

PHYSICAL TRANSPORTATION COSTS

At least six (6) months prior to the delivery of the first Liquefaction Train under the Agreement, Seller shall provide to Buyer for Buyer’s review and approval, such approval not to be unreasonably withheld, conditioned or delayed, a plan for the delivery of the Liquefaction Trains in accordance with the delivery schedule, including the identity of the transportation vendors and the estimated Transportation Costs for the Agreement.

 

K-1


APPENDIX L

LIQUIDATED DAMAGE AMOUNTS

 

I.

Delivery Delay Liquidated Damages (Clause 6.4(c)(i)(l)):

 

Day

   Liquidated Damage
Amount
  Liquidated Damage
Amount (in aggregate)

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]


II.

Delivery Delay Liquidated Damages (Clause 6.4(c)(ii)(l)):

 

Day

   Liquidated Damage
Amount
  Liquidated Damage
Amount (in aggregate)

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]


III.

Performance Delay Liguidated Damages (Clause 25.3(b)(i)(x)(l)):

 

Day

   Liquidated Damage
Amount
  Liquidated Damage
Amount (in aggregate)

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]


IV.

Performance Delay Liguidated Damages (Clause 25.3(b)(i)(y)(l)):

 

Day

   Liquidated Damage
Amount
  Liquidated Damage
Amount (in aggregate)

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]


I.

Performance Delay Liquidated Damages (Clause 25.3(b)(ii)(l)):

 

Day

   Liquidated Damage
Amount
  Liquidated Damage
Amount (in aggregate)

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]

[***]

   [***]   [***]


APPENDIX M

CONTRACT PRICE ADJUSTMENTS

Part 1

The Contract Price shall be adjusted by the following adjustment index formula, provided that such adjustment shall (a) not be subject to any compounding and (b) be limited to a maximum reduction of [***], and maximum increase of [***], per annum:

[***]

where:

 

   

P1 = Calculated escalated Contract Price

 

   

PO = Original Contract Price

 

   

Index 1 = applicable index for the month of issuance of LNTP, or FNTP if LNTP is not issued,

 

   

Index 0 = applicable base index for the month of the Effective Date

and:

[***]


Part 2

The Contract Price shall be adjusted for foreign exchange as follows:

 

(i)

An amount in US Dollars equal to [***] of the Contract Price shall be converted from US Dollars into Euro at the exchange rate for US Dollars to Euro as of the Effective Date, which is stipulated to be [***] US Dollars to [***] Euro.

 

(ii)

The Euro amount determined pursuant to clause (i) shall be re-converted to US Dollars on the day of issuance of LNTP, or FNTP if LNTP is not issued, using the Euro reference exchange rate for the US Dollar published by the European Central Bank at link https://www.ecb.europa.eu/stats/policy and exchange rates/euro reference exchange rates/ html/index.en.html as determined by the Parties.

 

(iii)

An amount in US Dollars equal to [***] of the Contract Price shall be subtracted from the re-converted US Dollar amount determined pursuant to clause (iii).

 

(iv)

lf the amount determined pursuant to clause (iii) is positive, it shall be added to the Contract Price by Change Order. If the amount determined pursuant to clause (iii) is negative, it shall be deducted from the Contract Price by Change Order.


Part 3

The Contract Price shall be further adjusted by the following adjustment index formula, provided that such adjustment shall (a) not be subject to any compounding and (b) be limited to a maximum reduction of [***], and maximum increase of [***], per annum:

[***]

where:

 

   

P1 = Calculated escalated Contract Price

 

   

PO = Original Contract Price

 

   

Index 1 = applicable index for the month of issuance of LNTP, or FNTP if LNTP is not issued,

 

   

Index 0 = applicable base index for the month of the Effective Date

and:

[***]


Part 4

The Contract Price shall be adjusted for foreign exchange as follows:

 

(i)

An amount in US Dollars equal to [***] of the Contract Price shall be converted from US Dollars into Euro at the exchange rate for US Dollars to Euro as of the LNTP issuance date.

 

(ii)

The Euro amount determined pursuant to clause (i) shall be re-converted to US Dollars on the day of issuance of FNTP, using the Euro reference exchange rate for the US Dollar published by the European Central Bank at link https://www.ecb.europa.eu/stats/policy and exchange rates/euro reference exchange rates/ html/index.en.html as determined by the Parties.

 

(iii)

An amount in US Dollars equal to [***] of the Contract Price shall be subtracted from the re-converted US Dollar amount determined pursuant to clause (iii).

If the amount determined pursuant to clause (iii) is positive, it shall be added to the Contract Price by Change Order. If the amount determined pursuant to clause (iii) is negative, no amount shall be deducted from the Contract Price by Change Order.

Exhibit 10.49

GUARANTY AGREEMENT

THIS GUARANTY AGREEMENT (this “Guaranty”) is made as of the 13th day of April, 2023, by Baker Hughes Holdings LLC, a limited liability company duly organized and existing under the laws of the State of Delaware, with its primary office at 17021 Aldine Westfield Road, Houston, Texas 77073 (herein called “Guarantor”), for the benefit of Venture Global CP2 LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware, with its primary office at 1001 19th Street North, Suite 1500, Arlington, VA 22209 (herein called “Buyer”). Guarantor and Buyer are individually referred to herein as a “Party” and collectively as the “Parties.”

RECITALS:

WHEREAS, Baker Hughes Energy Services LLC, a limited liability company organized and existing under the laws of the State of Delaware, with a place of business at 17021 Aldine Westfield Road, Houston, Texas 77073 (herein called “Seller”) is an affiliate of Guarantor;

WHEREAS, Buyer and Seller have entered into a Purchase Order Contract for the Sale of Liquefaction Train System dated as of April 7, 2023 (together with the schedules, annexes, and exhibits thereto and as the same may be amended from time to time, herein called the “Contract”), for the supply of certain natural gas liquefaction equipment by Seller;

WHEREAS, the Contract requires Guarantor to guarantee Seller’s performance under the Contract for the benefit of Buyer; and

WHEREAS, Guarantor indirectly owns the majority of the membership interests of Seller and, as ultimate parent company of Seller, is willing to enter into this Guaranty in satisfaction of the conditions of the Contract.

NOW, THEREFORE, in consideration of the premises and mutual covenants set forth herein, the Parties hereto agree as follows:

1. Subject to Section 2, Guarantor unconditionally, absolutely and irrevocably guarantees to Buyer, and its successors and assigns, as and for its own obligation, and not as a surety, that in the event of Seller failing in any respect to perform or observe any obligation owed by Seller to Buyer, whether now existing or hereafter arising, under the terms and provisions of the Contract, Guarantor shall within ten (10) Working Days (as such term is defined in the Contract) upon first demand in writing by Buyer (a) perform or take such steps as are necessary to achieve performance or observance of such obligations and (b) indemnify, defend and hold harmless the Buyer Parties (as such term is defined in the Contract) against any and all losses, damages, claims, costs, charges, and expenses, howsoever arising, from the said failure to the extent of Seller’s liability under the Contract.

2. Notwithstanding anything to the contrary contained in this Guaranty or the Contract, the Guarantor’s aggregate liability under this Guaranty at any time prior to the issuance of FNTP shall not exceed the applicable Maximum Termination Fee.


3. This Guaranty constitutes an independent guaranty, and is not conditioned on or contingent upon or modified, impaired or prejudiced by: (a) any attempt to enforce in whole or in part any obligations of Seller to Buyer; (b) the existence or continuance of Seller as a legal entity; (c) the consolidation or merger of Seller with or into any other entity; (d) the sale, lease or disposition by Seller of all or substantially all of its assets to any other entity; (e) the bankruptcy or insolvency of Seller or the making by Seller of a general assignment for the benefit of creditors; (f) any other security now or hereafter held by Buyer as security for the obligations of Seller; (g) the compromise, settlement, release, waiver, change, modification, or termination of any of Seller’s obligations under the Contract; (h) the extension of time for payment of any amounts due from Seller or of the time for performance of any of Seller’s obligations under the Contract; or (i) the failure, omission, delay or lack on the part of Buyer to enforce or exercise any right, power or remedy under or pursuant to the terms of the Contract or this Guaranty.

4. Guarantor’s payment and performance shall be subject to the defenses and the limits on Seller’s liability under the Contract. Guarantor agrees to make any payment due hereunder upon first written demand, without set-off or counterclaim and without any legal formality, such as protest or notice being necessary, and waives all privileges or rights which it may have as a guarantor, including (a) any right to require Buyer to claim payment or to exhaust remedies against Seller or any other person, (b) notice of any fact which might substantially increase Buyer’s risk; (c) notice of presentment for payment, demand or protest and notice thereof as to any instrument; (d) notice of Seller’s default; (e) any defense arising by reason of any incapacity, lack of authority or disability; (f) any defense arising because of the exercise of any right or remedy available to, or election made by, Buyer pursuant to the U.S. Bankruptcy Code and (g) all other notices and demands to which Guarantor might otherwise be entitled.

5. The obligations of Guarantor hereunder are primary and original obligations and shall continue in full force and effect after expiry or termination of the Contract until all of Seller’s obligations and liabilities under the Contract have been fully discharged, without regard to future changes in conditions, including change in law or any invalidity or irregularity with respect to the execution and delivery of this Guaranty.

6. Guarantor irrevocably and absolutely waives any and all rights of subrogation, contribution, indemnification, reimbursement or similar rights against Seller with respect to this Guaranty. In addition, Guarantor will not exercise any rights which it may acquire by way of subrogation under this Guaranty by any payment made hereunder or otherwise, until all of Seller’s obligations owed to Buyer shall have indefeasibly been performed or paid in full.

7. This Guaranty shall continue to be effective or be reinstated, as the case may be, if at any time any payment by Guarantor or Seller to Buyer is annulled, set aside, invalidated, declared to be fraudulent or preferential, rescinded or must otherwise be returned, refunded or repaid by Buyer upon the insolvency, bankruptcy, reorganization, dissolution or liquidation of Seller, Guarantor or otherwise, and is so rescinded or returned to the party or parties making such payment, all as though such payment had not been made.


8. This Guaranty and the undertakings herein contained shall be binding upon the successors and assigns of Guarantor and shall extend to and inure for the benefit of the successors or permitted assignees of Buyer. Guarantor may not assign its rights and obligations hereunder or assign or otherwise transfer this Guaranty or any interest herein, without the prior written consent of Buyer. Buyer may assign or transfer all or any of its right, title and interest in this Guaranty in connection with any assignment of the Contract in accordance with the requirements specified therein, including a collateral assignment to Lenders (as such term is defined in the Contract). No person other than Buyer or such permitted assignees or transferees as described above is intended as a beneficiary of this Guaranty nor shall any such person have any rights hereunder.

9. No assignment or transfer of the Contract or this Guaranty shall operate to extinguish or diminish the liability of Guarantor hereunder.

10. This Guaranty shall terminate and shall no longer be of any force or effect, and shall promptly be returned by Buyer to Guarantor, upon the earlier to occur of (a) the performance by Seller of all of its obligations under the Contract or (b) the delivery by Seller of replacement credit support pursuant to and in accordance with the Contract.

11. In the event there is any dispute under the Contract that relates to a sum being claimed under this Guaranty, which dispute is submitted to arbitration in accordance with the Contract, the obligations under this Guaranty with respect to such sum being claimed shall be suspended pending the outcome of such arbitration and Guarantor further agrees that any award resulting from such arbitration shall be conclusive and binding on it for purposes of determining its obligation under this Guaranty.

12. Guarantor represents and warrants to Buyer that: (a) Guarantor is a limited liability company duly formed, validly existing and in good standing under the laws of its jurisdiction of formation; (b) the execution, delivery and performance by Guarantor of this Guaranty have been duly authorized by all necessary actions on the part of Guarantor; and (c) this Guaranty constitutes a legally binding obligation of Guarantor, except as the enforceability hereof may be limited by applicable bankruptcy, insolvency, moratorium and other laws affecting Buyer’s rights generally and by equitable principles (regardless of whether enforcement is sought in equity or at law).

13. Subject to Section 2, Guarantor agrees to pay all expenses (including court costs and reasonable attorney’s fees) incurred by Buyer in connection with defending and enforcing its rights under this Guaranty.

14. This Guaranty shall be governed by and construed in accordance with the laws of the State of New York, excluding only those provisions regarding conflict of laws.

15. The Parties irrevocably waive any objections, which they may have now or hereafter to (a) the personal or subject matter jurisdiction of the federal or state courts located in the State of New York, (b) the venue of any proceedings brought in the federal or state courts located in the State of New York, or (c) that such proceedings have been brought in a non-convenient forum. The Parties irrevocably agree that any final judgment (after appeal or expiration of time for appeal) entered by any such courts shall be conclusive and binding upon the Parties and may be enforced in the courts or any other jurisdiction to the fullest extent permitted by applicable law.

[Signature page follows]


IN WITNESS WHEREOF, the Parties hereto have caused this Guaranty to be executed by their respective authorized representatives as of the date first written above.

 

BAKER HUGHES HOLDINGS LLC     VENTURE GLOBAL CP2 LNG, LLC
By:  

/s/ Fernando Contreras

    By:  

/s/ Jonathan W. Thayer

Name:  

Fernando Contreras

    Name:  

Jonathan W. Thayer

Title:  

VP, Legal Governance & Corporate Securities

    Title:  

Chief Financial Officer

Exhibit 10.50

GUARANTY AGREEMENT

THIS GUARANTY AGREEMENT (this “Guaranty”) is made as of the 4th day of May, 2023, by Venture Global LNG, Inc., a Delaware corporation, with its primary office at 1001 19th Street North, Suite 1500, Arlington, VA 22209 (herein called “Guarantor”), for the benefit of Baker Hughes Energy Services LLC, a limited liability company organized and existing under the laws of the State of Delaware, with a place of business at 17021 Aldine Westfield Road, Houston, Texas 77073 (herein called “Seller”). Guarantor and Seller are individually referred to herein as a “Party” and collectively as the “Parties.”

RECITALS:

WHEREAS, Venture Global CP2 LNG, LLC, a limited liability company duly organized and existing under the laws of the State of Delaware, with a place of business at 1001 19th Street North, Suite 1500, Arlington, VA 22209 (herein called “Buyer”) is a wholly owned affiliate of Guarantor;

WHEREAS, Buyer and Seller entered into a Purchase Order Contract for the Sale of Liquefaction Train System with Seller dated as of April 7, 2023 (together with the schedules, annexes, and exhibits thereto and as the same may be amended from time to time, herein called the “Contract”), for the supply of certain natural gas liquefaction equipment by Seller;

WHEREAS, the Contract contemplates that Guarantor may guarantee Buyer’s performance under the Contract for the benefit of Seller; and

WHEREAS, Guarantor indirectly owns all of the outstanding membership interests of Buyer and, as ultimate parent company of Buyer, is willing to enter into this Guaranty in satisfaction of the conditions of the Contract.

NOW, THEREFORE, in consideration of the premises and mutual covenants set forth herein, the Parties hereto agree as follows:

1. Subject to Section 2, Guarantor unconditionally, absolutely and irrevocably guarantees to Seller, and its successors and assigns, as and for its own obligation, and not as a surety, that in the event of Buyer failing in any respect to perform or observe any obligation owed by Buyer to Seller, whether now existing or hereafter arising, under the terms and provisions of the Contract, Guarantor shall within ten (10) Working Days (as such term is defined in the Contract) upon first demand in writing by Seller (a) perform or take such steps as are necessary to achieve performance or observance of such obligations and (b) shall indemnify, defend and hold harmless the Seller Parties (as such term is defined in the Contract) against any and all losses, damages, claims, costs, charges, and expenses, howsoever arising, from the said failure to the extent of Buyer’s liability under the Contract.

2. Notwithstanding anything to the contrary contained in this Guaranty or the Contract, the Guarantor’s aggregate liability under this Guarantee at any time prior to Financial Closing shall not exceed the applicable Maximum Termination Fee.


3. This Guaranty constitutes an independent guaranty, and is not conditioned on or contingent upon or modified, impaired or prejudiced by: (a) any attempt to enforce in whole or in part any obligations of Buyer to Seller; (b) the existence or continuance of Buyer as a legal entity; (c) the consolidation or merger of Buyer with or into any other entity; (d) the sale, lease or disposition by Buyer of all or substantially all of its assets to any other entity; (e) the bankruptcy or insolvency of Buyer or the making by Buyer of a general assignment for the benefit of creditors; (f) any other security now or hereafter held by Buyer as security for the obligations of Buyer; (g) the compromise, settlement, release, waiver, change, modification, or termination of any of Buyer’s obligations under the Contract; (h) the extension of time for payment of any amounts due from Buyer or of the time for performance of any of Buyer’s obligations under the Contract; or (i) the failure, omission, delay or lack on the part of Seller to enforce or exercise any right, power or remedy under or pursuant to the terms of the Contract or this Guaranty.

4. Guarantor’s payment and performance shall be subject to the defenses and the limits on Buyer’s liability under the Contract. Guarantor agrees to make any payment due hereunder upon first written demand, without set-off or counterclaim and without any legal formality, such as protest or notice being necessary, and waives all privileges or rights which it may have as a guarantor, including (a) any right to require Seller to claim payment or to exhaust remedies against Buyer or any other person, (b) notice of any fact which might substantially increase Seller’s risk; (c) notice of presentment for payment, demand or protest and notice thereof as to any instrument; (d) notice of Buyer’s default; (e) any defense arising by reason of any incapacity, lack of authority or disability; (f) any defense arising because of the exercise of any right or remedy available to, or election made by, Seller pursuant to the U.S. Bankruptcy Code and (g) all other notices and demands to which Guarantor might otherwise be entitled.

5. The obligations of Guarantor hereunder are primary and original obligations and, subject to Section 10, shall continue in full force and effect after expiry or termination of the Contract until all of Buyer’s obligations and liabilities under the Contract have been fully discharged, without regard to future changes in conditions, including change in law or any invalidity or irregularity with respect to the execution and delivery of this Guaranty.

6. Guarantor irrevocably and absolutely waives any and all rights of subrogation, contribution, indemnification, reimbursement or similar rights against Buyer with respect to this Guaranty. In addition, Guarantor will not exercise any rights which it may acquire by way of subrogation under this Guaranty by any payment made hereunder or otherwise, until all of Buyer’s obligations owed to Seller shall have indefeasibly been performed or paid in full.

7. This Guaranty shall continue to be effective or be reinstated, as the case may be, if at any time any payment by Guarantor or Buyer to Seller is annulled, set aside, invalidated, declared to be fraudulent or preferential, rescinded or must otherwise be returned, refunded or repaid by Seller upon the insolvency, bankruptcy, reorganization, dissolution or liquidation of Buyer, Guarantor or otherwise, and is so rescinded or returned to the party or parties making such payment, all as though such payment had not been made.


8. This Guaranty and the undertakings herein contained shall be binding upon the successors and assigns of Guarantor and shall extend to and inure for the benefit of the successors or permitted assignees of Seller. Guarantor may not assign its rights and obligations hereunder or assign or otherwise transfer this Guaranty or any interest herein, without the prior written consent of Seller. Seller may assign or transfer all or any of its right, title and interest in this Guaranty in connection with any assignment of the Contract in accordance with the requirements specified therein. No person other than Seller or such permitted assignees or transferees as described above is intended as a beneficiary of this Guaranty nor shall any such person have any rights hereunder.

9. No assignment or transfer of the Contract or this Guaranty shall operate to extinguish or diminish the liability of Guarantor hereunder.

10. This Guaranty shall terminate and shall no longer be of any force or effect, and shall promptly be returned by Seller to Guarantor, upon the earlier to occur of (a) the assignment of the Contract to the EPC Contractor in accordance with the Contract and delivery by the EPC Contractor of replacement credit support in accordance with Clauses 4 and 7 of the Contract or (b) Financial Closing.

11. In the event there is any dispute under the Contract that relates to a sum being claimed under this Guaranty, which dispute is submitted to arbitration in accordance with the Contract, the obligations under this Guaranty with respect to such sum being claimed shall be suspended pending the outcome of such arbitration and Guarantor further agrees that any award resulting from such arbitration shall be conclusive and binding on it for purposes of determining its obligation under this Guaranty.

12. Guarantor represents and warrants to Seller that: (a) Guarantor is a corporation duly incorporated, validly existing and in good standing under the laws of its jurisdiction of incorporation; (b) the execution, delivery and performance by Guarantor of this Guaranty have been duly authorized by all necessary actions on the part of Guarantor; and (c) this Guaranty constitutes a legally binding obligation of Guarantor, except as the enforceability hereof may be limited by applicable bankruptcy, insolvency, moratorium and other laws affecting Seller’s rights generally and by equitable principles (regardless of whether enforcement is sought in equity or at law).

13. Subject to Section 2, Guarantor agrees to pay all expenses (including court costs and reasonable attorney’s fees) incurred by Seller in connection with defending and enforcing its rights under this Guaranty.

14. This Guaranty shall be governed by and construed in accordance with the laws of the State of New York, excluding only those provisions regarding conflict of laws.

15. The Parties irrevocably waive any objections, which they may have now or hereafter to (a) the personal or subject matter jurisdiction of the federal or state courts located in the State of New York, (b) the venue of any proceedings brought in the federal or state courts located in the State of New York, or (c) that such proceedings have been brought in a non-convenient forum. The Parties irrevocably agree that any final judgment (after appeal or expiration of time for appeal) entered by any such courts shall be conclusive and binding upon the Parties and may be enforced in the courts or any other jurisdiction to the fullest extent permitted by applicable law.

[Signature page follows]


IN WITNESS WHEREOF, the Parties hereto have caused this Guaranty to be executed by their respective authorized representatives as of the date first written above.

 

BAKER HUGHES ENERGY SERVICES LLC     VENTURE GLOBAL LNG, INC.
By:       By:  

/s/ Jonathan W. Thayer

Name:       Name:  

Jonathan W. Thayer

Title:       Title:  

Chief Financial Officer

Exhibit 10.51

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

 

   STATE OF LOUISIANA    Execution Version
   PARISH OF CAMERON   

AMENDED AND RESTATED GROUND LEASE AGREEMENT

(228 Acres)

This AMENDED AND RESTATED GROUND LEASE AGREEMENT (this “Ground Lease”) is executed and effective as of July 15, 2019, by and between Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Tenant”) and JADP Venture, LLC, a Louisiana limited liability company (the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Cameron Parish, Louisiana, which comprises approximately two hundred twenty-eight (228) acres identified herein as the Project Site as further defined below; and

WHEREAS, the Tenant is desirous of leasing land owned by the Landlord for the construction and development and operation of a natural gas liquefaction facility as generally described in Exhibit 2 (the “Facility”) and other uses permitted by this Ground Lease; and

WHEREAS, the Landlord and the Tenant desire to lease such land in order to develop the land with the Facility and thereby create and provide employment opportunities for the inhabitants of Southwest Louisiana, which will add to the welfare and prosperity of the persons residing within the geographic limits of numerous surrounding Parishes and throughout the State of Louisiana; and

WHEREAS, in connection with the foregoing, the Landlord and the Tenant are parties to that certain Ground Lease Agreement, dated as of March 14, 2019 (the “Ground Lease Commencement Date”), as amended by the First Amendment to Ground Lease Agreement, dated as of March 25, 2019 (as amended, the “Original Ground Lease”); and

WHEREAS, the Landlord and the Tenant have agreed to amend and restate the Original Ground Lease in its entirety on the terms and conditions set forth in this Ground Lease; and

WHEREAS, in accordance with the above, the Tenant has executed this Ground Lease and offers fair value to the Landlord as cause and consideration for this Ground Lease; and

NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this Ground Lease, and the Parties herein covenant and agree as follows:

 


l. Definitions.

As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

Adjustment Period” has the meaning set forth in Section 4.1(c).

Affiliate” means any Person controlled by, controlling or under common control with the Landlord or the Tenant, as applicable. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of thirty percent (30%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.

Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Project Site.

Bankruptcy Proceeding” has the meaning set forth in Section 23.10.

Bona Fide Offer” means a bona fide written offer to purchase all or any portion of the Project Site from a true, independent third party, who is not an Affiliate of the Landlord and who is otherwise making the offer in good faith and on an arms-length basis that the Landlord desires to accept.

Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in the state of New York are authorized or required by law to close.

Consumer Price Index” has the meaning set forth in Section 4.2.

Corps” has the meaning set forth in Section 8.2(a).

Corrective Measures” has the meaning set forth in Section 9.4(b).

CPI Adjustment” has the meaning set forth in Section 4.1.

CPI Disagreement Notice” has the meaning set forth in Section 4.2.

CPI Notice” has the meaning set forth in Section 4.2.

CPI Percentage Increase” has the meaning set forth in Section 4.2.

Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Law relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

 

2


Event of Default” has the meaning set forth in Section 15.1.

Extended Term” has the meaning set forth in Section 3.2(a).

Facility” has the meaning set forth in the Recitals hereof.

Facility Contractors” means, collectively, the Persons engaged by the Tenant to construct the Facility and/or develop the Project, Project Site and/or Improvements.

Facility Contracts” means, collectively, the contracts entered into by the Tenant in connection with the design, construction, equipment procurement, operation and maintenance of the Facility and/or the Project, Project Site and/or Improvements.

Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Project or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders.

Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include, but not be limited to, the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, droughts, floods, washouts, explosions, breakage or accident or necessity of repairs to machinery or equipment or lines of pipe; (ii) weather related events affecting an entire geographic region; (iii) acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, terrorism, discovery of burial grounds or human remains or legally protected artifacts, insurrections or wars; (iv) the failure or interruption of performance by the Tenant’s engineering, procurement and construction contractor or any subcontractors of such contractor to the extent caused by an event of Force Majeure under this Ground Lease; (v) the failure or interruption of performance by the Tenant’s suppliers by reason of such supplier’s valid declaration of an event that would constitute an event of force majeure under the Tenant’s contract with such supplier; (vi) governmental actions such as necessity for compliance with any court order, law, statute, ordinance, regulation, or policy having the effect of law promulgated by a Governmental Authority having jurisdiction, or that restrict the Tenant’s ability to reasonably construct and/or operate the Facility and/or Project or any delay in issuance or effectiveness of any Governmental Approval that has been properly applied for by the Tenant that is required to construct and/or operate the Facility and/or Project.

Governmental Approval” means any authorization, waiver, consent, approval, license, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority.

 

3


Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

Ground Lease” has the meaning set forth in the Preamble hereof.

Ground Lease Commencement Date” has the meaning set forth in the Recitals hereof.

Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

Hazardous Substances Law” means the published cleanup standards of any Governmental Authority with jurisdiction over the Project Site and any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law and similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including, but not limited to, the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent they relate to the handling of and exposure to Hazardous Substances.

 

4


Improvements” means any and all improvements made by Tenant, in its sole discretion, to the Project Site, including but not limited to, improvements relating to the loading, unloading, handling, treatment, processing, producing, transporting, distributing, selling, metering and/or storing of (i) natural gas, natural gas liquids, and other natural gas products, derivatives and by-products and (ii) other petroleum and hydrocarbon liquids, gases, products, derivatives and by-products, including but not limited to (A) the importation, regasification, production, exportation, liquefaction, refinement, enhancement, other treatment and transportation (including by ship, pipeline, truck or rail) of LNG, and LNG by-products and additives and (B) the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of any improvements, component parts and other constructions, fixtures, facilities, equipment and/or appurtenances (including natural gas pipelines, natural gas liquids extraction, processing and delivery facilities, acid gas removal units, natural gas liquefaction trains, LNG regasification facilities, and other treatment facilities, cryogenic pipelines, LNG storage tanks, petroleum and other hydrocarbon liquids storage facilities, nitrogen storage and processing facilities, power generation and transmission infrastructure, marine, rail and trucking receipt, delivery and servicing facilities (including piers, marine terminals, bulkheads, wharfs, docks, inlets, wetslips, moonpools, moorings, jetties, and loading and unloading equipment), and other utilities and facilities (including berms, open space, security fencing, control rooms, offices, warehouses, parking and yards), in each case, necessary, ancillary or desirable to the Tenant in connection with the foregoing.

Initial Term” has the meaning set forth in Section 3.1.

Landlord” has the meaning set forth in the Preamble hereof.

Landlord Estoppel” has the meaning set forth in Section 23.11(a).

Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, affiliates, invitees, agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Project Site and/or Landlord’s Improvements.

Landlord’s Event of Default” has the meaning set forth in Section 16.1.

Landlord Indemnitee” has the meaning set forth in Section 9.1.

Landlord’s Improvements” has the meaning set forth in Section 6.1.

Lease Year” means a period of twelve (12) consecutive full calendar months. The first Lease Year shall begin on the Ground Lease Commencement Date. Each succeeding Lease Year shall commence upon the anniversary of the first day of the previous Lease Year.

Leasehold Lenders” has the meaning set forth in Section 23.1.

Leasehold Loan” has the meaning set forth in Section 23.1.

Leasehold Mortgage” has the meaning set forth in Section 23.1.

 

5


Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

LNG” means liquefied natural gas.

Minerals” has the meaning set forth in Section 8.2(b).

New Lease” has the meaning set forth in Section 23.9(a).

Non-Disturbance Agreement” has the meaning set forth in Section 23.11(c).

Option Agreement” means the Real Estate Lease Option Agreement between Landlord and Tenant, dated as of October 1, 2015.

Original Ground Lease” has the meaning set forth in the Recitals hereof.

Party” or “Parties” has the meaning set forth in the Preamble hereof.

Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

Project” means the development, permitting, financing, construction, ownership, operation and/or maintenance of the Facility and the Improvements on the Project Site.

Project Site” means the real (immovable) property of approximately two hundred twenty-eight (228) acres described in the legal description set forth in Exhibit 1-A, and illustrated by the Survey Map attached as Exhibit 1-B, including any waterway areas, upon which the Facility and other Improvements will be located and which real (immovable) property is owned by the Landlord.

Property Taxes” means all real (immovable) and personal (movable) property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

Removal Period” means the one thousand two hundred fifty (1250) day period that is required by Tenant to remove any and all of Tenant’s Property, including the Facility and/or Improvements, from the Project Site in accordance with Section 7.1.

Rent” has the meaning set forth in Section 4.1.

 

6


Surface Waiver” has the meaning set forth in Section 8.2(b).

Survey Map” means the ALTA survey of the Project Site, dated April 30, 2015, by Lonnie G. Harper & Associates, Inc., attached as Exhibit 1-B.

Tenant” has the meaning set forth in the Preamble hereof.

Tenant Estoppel” has the meaning set forth in Section 23.11(b).

Tenant Indemnitee” has the meaning set forth in Section 9.3.

Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Project Site by or on behalf of Tenant, including the Facility and any Improvements.

Tower Lease” has the meaning set forth in Section 2.2.

2. Ground Lease Premises.

2.1 Date. The date of this Ground Lease is the Ground Lease Commencement Date.

2.2 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of the rents and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does lease to the Tenant and the Tenant hereby leases from the Landlord, the Project Site and Landlord’s Improvements subject to that certain Contract of Lease, by and between W.F. Henry, Jr., as trustee of the James Austin and Martha Davis Trust for Lonnie A. Davis, the James Austin and Martha Davis Trust for Wilma Davis Guthrie, and the James Austin and Martha Davis Trust for Mary Davis Henry and Carmen V. Gebhardt, Linda D. Dlouhy, Mary P. Davis Lakhdari and George A. Davis, as lessor, and American Tower, L.P. (successor in interest to Allied Tower Rentals, Inc.), as lessee, dated March 31, 1972, filed April 4, 1972, recorded under Clerk’s File No. 128954, in Conveyance Book 290, Page 330, and filed December 29, 1987, recorded under Clerk’s File No. 207239, in Conveyance Book 659, Page 168, as affected by that certain Assignment filed December 29, 1987, recorded under Clerk’s File No. 207243, in Conveyance Book 659, Page 192; as affected by that Lease Extension filed July 9, 1992, recorded under Clerk’s File No. 227748, in Conveyance Book 752, Page 332, as affected by that certain Extended Lease Agreement filed February 26, 1993, recorded under Clerk’s File No. 230176, in Conveyance Book 764, Page 750, as affected by that certain Addendum to Land Lease Agreement At Cameron #1 filed October 13, 1998, recorded under Clerk’s File No. 257320, in Conveyance Book 886, Page 323, as affected by that certain First Amendment to Lease dated February 23, 2006 as evidenced by that certain Memorandum of Lease filed May 16, 2006, recorded under Clerk’s File No. 297896, of the records of Cameron Parish, Louisiana, for so long as such Tower Lease remains in full force and effect.

 

7


2.3 Servitudes. In addition, the Landlord or its Affiliates, as applicable, shall without cost to the Tenant, grant from time to time to the Tenant and others designated by the Tenant any easements, servitudes, and rights of way for access and electricity, communications, gas, water, sewer, and other utility lines, products and materials from and to the Project Site over land and waterways that are adjacent to the Project Site and controlled by the Landlord or its Affiliates, sufficient to permit the Tenant to accomplish its purposes in connection with the Project.

3. Term

3.1 Initial Term. The initial term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on the thirtieth (30th) anniversary of the last day of the month immediately preceding the Ground Lease Commencement Date (the “Initial Term”).

3.2 Extensions.

(a) In consideration of and conditioned upon there being no uncured Event of Default on the part of the Tenant at the lime an option is exercised, the Landlord hereby grants unto the Tenant the option to lease the Project Site for four (4) additional ten (10) year terms. If the extension option is exercised in accordance with Section 3.2(b), the first of said additional terms shall commence upon the expiration of the Initial Term and extend for a period of ten (10) years and each of said additional terms commencing upon the expiration of the then current additional term and extending for a period of ten (10) years. Each of such additional terms is referred to herein as an “Extended Term”.

(b) The option to extend this Ground Lease of the Project Site as set forth in Section 3.2(a) must be exercised in each case, if at all, by written notice from the Tenant to the Landlord on or before the date that is three (3) months prior to the expiration of the Initial Term or then current Extended Term, as applicable. The failure of the Tenant to timely exercise the first Extended Term or any subsequent Extended Term shall automatically terminate the right of the Tenant to exercise its option to lease the Project Site in any subsequent Extended Term.

(c) All the terms and conditions of this Ground Lease shall be applicable to any Extended Term and the Rent payable by the Tenant for any Extended Term shall be in accordance with the provisions set forth in Section 4.

4. Rent.

4.1 Rent. Commencing upon the Ground Lease Commencement Date, the initial rent for the Project Site (“Rent”) shall be [***] per annum, payable in equal installments of [***] per month, adjusted upward every five (5) years thereafter during the Initial Term and during any Extended Term by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment during any Adjustment Period (as defined below) of greater than [***]. The period of time from the Ground Lease Commencement Date through March

 

8


14, 2024, and each five (5) year period thereafter shall be defined herein as an “Adjustment Period.” Any upward adjustment based on a CPI Percentage Increase (as defined below) to any payment under this Ground Lease shall hereinafter be referred to as a “CPI Adjustment.” Such Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month; provided, however, that (i) the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; and (ii) the first payment of Rent due upon the commencement of any new Adjustment Period will be owed and paid one month after the commencement of that Adjustment Period, in order to permit Tenant to calculate the CPI Percentage Increase, as set forth below.

4.2 CPI Adjustment. If CPI Percentage Increase (as defined below) is more than [***] for the relevant Adjustment Period, then the Rent payable during that Adjustment Period shall be adjusted upward by a percentage equal to the CPI Percentage Increase (as defined below) applicable to such Adjustment Period, but not to exceed an adjustment during any Adjustment Period of greater than [***]. The term “Consumer Price Index” shall mean the unadjusted Consumer Price Index for All Urban Workers, U.S. City Average, All Items, 1982-84= 100, calculated and published by the United States Department of Labor, Bureau of Labor Statistics. The “CPI Percentage Increase” shall mean, with respect to any Adjustment Period, [***]. For the avoidance of doubt, no CPI Adjustment shall be made to any payment due under this Ground Lease for any Adjustment Period if the result of such CPI Adjustment would be to (a) reduce the amount of such payment to an amount that is less than the amount of such payment due for the immediately preceding Adjustment Period or (b) to raise the amount of such payment to an amount that is greater than [***]. For illustrative purposes only, [***]. The CPI Percentage Increase for any Adjustment Period shall be calculated by the Tenant, and the Tenant shall deliver written notice to the Landlord describing such calculation in reasonable detail (a “CPI Notice”) no later than thirty (30) days after the commencement of any Adjustment Period. If the Landlord disagrees with the Tenant’s calculation of the CPI Percentage Increase, then the Landlord shall deliver to the Tenant written notice, describing the basis for such disagreement in reasonable detail (a “CPI Disagreement Notice”), not later than thirty (30) days after delivery of the CPI Notice. If the Landlord fails to deliver a CPI Disagreement Notice within thirty (30) days after delivery of any CPI Notice, then the Landlord shall be conclusively deemed to have agreed with the calculation of the CPI Percentage Increase set forth in such CPI Notice.

 

9


4.3 Due Date. Except as otherwise provided in this Ground Lease, all Rent payments shall be due in advance on the 1st calendar day of each month and payable by the 15th calendar day of each month during the entire term of this Ground Lease. If the 15th calendar day of a month falls on a day that is not a Business Day, then Rent shall be payable on the following Business Day.

4.4 Place of Payment. Except as otherwise provided herein, Rent shall be payable by check or wire transfer at the address or via wire instructions as the Landlord may specify in writing to the Tenant and the Tenant deem acceptable, from time to time.

5. Net Lease; Taxes and Utility Expenses.

5.1 Net Lease. This Ground Lease is a net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs, if any, of every kind and nature whatsoever relating to the Project Site except as expressly otherwise provided in this Ground Lease.

5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and Governmental Approval fees applicable to the Facility during the term of this Ground Lease.

(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on or related to the Project Site during the term of this Ground Lease. The Landlord shall promptly provide all Property Tax bills to the Tenant when they become available. Upon the latter of (i) one (1) month after receipt of such Property Tax bill from the Landlord or (ii) the due date of any such Property Taxes, the Tenant shall provide the Landlord with reasonable written evidence from the Cameron Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

5.3 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost, electricity, telephone, water, sewerage, gas, and other utility services to the Project Site; provided, however, the Landlord shall cooperate and, to the extent reasonably needed, facilitate the contracting of any easements, servitudes and/or rights of way, and grant easements, servitudes and rights of way in accordance with Section 2.3, as required by the Tenant for such utility connections and/or services.

6. Tenant and Landlord Improvements.

6.1 Landlord’s Improvements. “Landlord’s Improvements” are any and all improvements to the immovable property of the Project Site and any and all movable property in existence on the Project Site at the time of the Ground Lease Commencement Date. There are no Landlord’s Improvements.

 

10


6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install on the Project Site, the Facility and any Improvements during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. The Tenant shall be permitted to make any changes, improvements or alterations to the Project Site, including, without limitation, the Facility and any Improvements to the Project Site, during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. During the term of this Ground Lease, the Tenant has the right to make any changes, alterations, and/or improvements with respect to the Project as long as such changes, alterations, and/or improvements comply with Applicable Laws.

6.3 Governmental Approvals. The Landlord will cooperate and assist (and never oppose) the Tenant in obtaining any and all Governmental Approvals deemed necessary by Tenant for the Facility and all other Improvements to the Project Site, including with respect to Governmental Approvals from the Federal Energy Regulatory Commission and the Department of Energy. The Landlord will hereafter continue to be obligated to execute appropriate documentation to waive its right to require wetlands mitigation to be completed on the Project Site or other real (immovable) property owned by the Landlord, in such form as necessary to allow the Tenant to complete such wetlands mitigation at locations other than other real (immovable) property owned by the Landlord.

6.4 Tenant’s Property. The Tenant’s Property shall at all times be and remain the sole property of the Tenant.

6.5 Maintenance of Improvements.

(a) Tenant’s Obligation to Maintain. During the Initial Term or any Extended Term, as applicable, the Tenant will keep in reasonably good state of repair the Facility, the Improvements, open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Project Site by the Tenant, and the Tenant will, in its sole discretion and cost, repair such property as often as may be necessary in order to keep the Facility and Improvements in reasonably good repair and condition, except as set forth in Section 6.5(b).

(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease, the Landlord has no obligation to maintain the Project Site, Improvements and/or Landlord’s Improvements (if any) during the Initial Term and/or any Extended Term. The Landlord further agrees that there will be no Landlord improvements on the Project Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Project Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

 

 

11


7. Tenant’s Surrender of Project Site.

7.1 Surrender at End of Ground Lease. Subject to Section 6.4 and subject and subordinate to Section 23 and the rights of any Leasehold Lender under any Leasehold Mortgage, the Tenant shall and will on the last day of the Initial Term, or if extended, on the last day of the Extended Term hereof, surrender and deliver the Project Site to the Landlord, in good condition as is reasonably practicable (except as provided in Section 6.5 or Section 13), excepting normal wear and tear. If this Ground Lease is terminated for any reason or upon the expiration of the Initial Term and/or Extended Term (if extended) of this Ground Lease, the Tenant shall in good faith proceed with (i) any removal of the Facility and any and all Improvements and (ii) restoration, if any, of the Project Site to its condition prior to construction of the Facility and/or Improvements, in accordance with Applicable Laws. During the Removal Period, the Tenant shall have all access rights to the Project Site that are necessary to remove any and all of Tenant’s Property, including the Facility and/or Improvements. The Tenant shall also comply as required by any federal regulations of the Federal Energy Regulatory Commission or any other federal authority with respect to the Facility on the Project Site.

7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date the Tenant shall assume full dominion, control and responsibility for the Project Site, except to the extent specifically provided herein, to the extent provided under LSA - R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real (immovable) or personal (movable) property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its officers, representatives, agents, or employees or the Landlord’s misrepresentations or its breach of or default under this Ground Lease.

7.3 Holding Over. Except for the Removal Period, if the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, and shall not constitute a renewal or extension of the term of this Ground Lease.

8. Use.

8.1 Permitted Uses; Compliance with Laws; Permits. The Tenant may use the Project Site for any and all uses desired by the Tenant in compliance with all Applicable Laws. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the construction and maintenance of the Facility, the Improvements and/or for the Tenant’s use or activities on the Project Site. The Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Project and security of the Project Site, including, but not limited to, the timely filing, implementation, and enforcement of any security plan required by Applicable Laws. Any fine or penalty imposed by any Governmental Authority solely caused by the failure of the Tenant to comply with this provision, including any fine or penalty imposed upon the Landlord as owner of the Project Site as solely caused by the failure of the Tenant to comply with this provision, shall be the sole responsibility of the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall indemnify and hold harmless the Landlord from the payment of any such fine or penalty, and the Tenant may pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord.

 

12


8.2 Dirt Moving Activities; Permits; Timber.

(a) The Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Project Site, to the Project Site, and from portions of the Project Site to other portions of the Project Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Project Site and may do so in its discretion. The Tenant shall have the right to remove soil and spoil from, and to add fill to, the Project Site and to dredge the slip and turning basin and dredge and widen the Calcasieu Ship Channel, and deposit the dredge spoils on the Project Site (as allowed by Applicable Law), in each case in connection with the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of the Facility, and for the purpose of constructing, creating, expanding, operating and maintaining a marine terminal and ship turning basin. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Project Site, including without limitation, for any Improvements, reclamation of lands, erosion control, attainment of spoil, easements/servitudes and/or rights of way; provided that all costs associated with such efforts shall be the responsibility of the Tenant. Except only as provided in Section 8.2(b), the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Project Site, and all other rights on and to the Project Site. Any activities of the Landlord and/or its lessees or assignees or any other party shall not adversely affect the Project Site or the Facility or interfere with the Tenant’s operations or rights under this Ground Lease in any way. Nothing herein is intended to preclude the Landlord, from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation. The Tenant may freely remove any timber which is standing or lying on the Project Site as the Tenant deems necessary for the Tenant’s intended use of the Project Site. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights below the surface of the Project Site.

(b) To the extent the Landlord holds any rights to oil, gas, or other minerals (“Minerals”) in the Project Site, Landlord waives any and all rights of the Landlord or its lessees or assignees to use the surface of the Project Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the term of this Ground Lease, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means consistent with the terms and conditions of this Section 8.2(b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Facility or interfere with the Tenant’s operations or rights under this Ground Lease in any way.

 

13


8.3 Crossing. The Landlord shall assist the Tenant in the Tenant’s efforts to develop, at the Tenant’s cost, any roads and/or crossings or other Improvements across the Project Site and boundary lines of the Project Site to the adjacent land, including relocation of utilities, providing culverts for storm water drainage, and any other Improvements. The Tenant or others, excluding the Landlord, will pay the cost to relocate or modify the infrastructure for these roads and/or crossings and/or other Improvements. The Landlord shall not be required to incur any costs or expenses in its efforts to assist the Tenant.

8.4 Pipelines; Rights of Way. If at any time the Tenant notifies the Landlord that the Project requires an off-Project Site pipeline and/or pipeline servitude for the development of the Project at the Project Site, the Landlord shall use its best efforts to cause the applicable landowners and Governmental Authorities to grant the pertinent approvals to achieve the pipeline and/or pipeline right of way. The Landlord shall not be required to incur any costs or expenses in its efforts to assist the Tenant.

9. Indemnification.

9.1 Tenant’s General Agreement to Indemnify. The Tenant releases the Landlord, its officers, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, witness fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Landlord Indemnitee arising out of (i) the use or occupancy of the Project Site by the Tenant, its officers, representatives, agents, and employees, (ii) the construction or operation of the Project by the Tenant, its officers, representatives, agents, and employees, (iii) any claim arising out of the use, occupancy, construction or operation of the Project Site by the Tenant, its officers, representatives, agents, and employees, and (iv) activities on or about the Project Site by the Tenant, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, operation, maintenance, or repair of the Facility, the Improvements, or the Project Site by the Tenant, its officers, representatives, agents, and employees; provided, however, that any such claim, liability, obligation, damage or penalty arising as a result of the negligence or willful misconduct of any Landlord Indemnitee shall be excluded from this indemnity. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9.2 and 9.4 and not this Section 9.1.

9.2 Tenant’s Environmental Indemnification. For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with all Environmental Laws applicable to the Tenant, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Project Site. The Tenant agrees to indemnify and hold harmless the Landlord Indemnitee against and in respect of any and all

 

14


damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorney, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth above in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Project Site or any violation of any Environmental Law with respect to the Project Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, and maintenance activities or facilities and not caused by the Landlord’s Activities or Landlord’s Improvements.

9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Project Site by the Landlord, its officers, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Project Site by the Landlord, its officers, representatives, agents, and employees, and (iii) activities on or about the Project Site by the Landlord, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation, damage or penalty arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope but not be limited to any and all claims or actions for wrongful death, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.4 and not this Section 9.3.

9.4 Landlord’s Environmental Indemnification.

(a) For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Project Site. The Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorneys, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances, or (ii) any actual or alleged violation of Environmental Laws, in the case of each of subclauses (i) and (ii), where the presence, discharge

 

15


or release of such Hazardous Substances or violation of Environmental Law arises or occurs (1) at, on or from the Project Site on or prior to the Ground Lease Commencement Date or (2) at, on or from the Project Site or any other site as a result of or relating to the Landlord’s Activities or facilities or Landlord’s Improvements, whether before, on or after the Ground Lease Commencement Date, or (iii) the Landlord’s breach of the covenant set forth above in this Section 9.4 or (iv) any environmental condition of contamination on the Project Site or any violation of any Environmental Law with respect to the Project Site to the extent occurring after the Ground Lease Commencement Date and caused by the Landlord’s Activities or facilities.

(b) If Hazardous Substances become present or are discharged onto the Project Site as a result of the Landlord’s Activities or otherwise exist at the Project Site on or prior to the Ground Lease Commencement Date, the Tenant shall so notify the Landlord in writing as soon as practicable after the Tenant’s discovery thereof. Except with respect to Hazardous Substances that become present or are discharged onto the Project Site as a result of the Landlord’s Activities, such discovery and notice to the Landlord must occur within the Initial Term of this Ground Lease for the Landlord to have any obligation to perform any Corrective Measures (as hereinafter defined). Except as provided in the following sentence, upon receipt of such notice from the Tenant, the Landlord shall have a reasonable period of time to undertake, at its own expense, but subject to a limit of $5,000,000, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority (“Corrective Measures”), except that such Corrective Measures shall not unreasonably interfere with the construction, operation or maintenance of the Facility and/or interfere the Improvements by Tenant. At its discretion, upon written notice to the Landlord, the Tenant shall have the right to undertake such Corrective Measures and the Landlord shall reimburse the Tenant up to a total amount of $5,000,000 (or Tenant may offset against Rent) for its reasonable and necessary documented costs therefor within thirty (30) days after receipt of an invoice by the Landlord (including any costs associated with the work stoppage or interference with the ability of any Facility Contractor to perform its respective obligations under the Facility Contracts (including mobilization and de-mobilization costs, suspension costs, storage costs, rescheduling penalties, and all other direct and indirect costs incurred by the Tenant or any Facility Contractor (and its respective subcontractors) as a result of any delay caused by such Corrective Measures)). The Party not controlling the Corrective Measures under this Section 9.4(b) shall have a reasonable right of participation in the Corrective Measures, consisting of the right to (i) receive copies of material reports, work plans and correspondence relating to the Corrective Measures, (ii) the right to review and comment on draft reports and work plans (and all prompt and reasonable comments shall be considered and addressed by the controlling Party in good faith), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.4(b) shall not supersede or diminish the provisions or the Landlord’s obligations under Section 9.4(a).

9.5 Survival of Indemnities. The foregoing indemnities shall survive the Initial Term, any Extended Term, and the Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

 

 

16


10. Insurance.

10.1 Tenant Insurance. Tenant shall carry or cause to be carried commercial general liability insurance with respect to the Project Site and the uses and activities of the Tenant thereon with minimum limits of [***]. The Tenant may elect to be self-insured in amounts greater than those minimum limits. In the event the Tenant procures commercial general liability insurance, the Landlord will be named as an additional insured.

10.2 Landlord Insurance. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Project Site and/or any activities of the Landlord with respect to the Project Site in its reasonable business discretion. The Landlord may elect to be self-insured.

11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. The Landlord shall not create or permit to be created or to remain in connection with the Project Site, the Facility, the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Project Site or upon the Landlord’s interest in the Project Site or upon the Tenant’s interest in its leasehold of the Project Site, in accordance with Section 11.2.

11.2 Discharge of Liens.

(a) If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Project Site or any part thereof in connection with the Facility, the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Project Site or any part thereof in connection with the Facility, the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

(b) If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such Lien by deposit or by bonding proceedings. Any amount so paid by the non-responsible Party and all costs and expenses incurred by the non-responsible Party in connection therewith, including reasonable attorneys’ fees together with interest thereon at one percent (1%) per annum above the Wall Street Journal Prime Rate of interest published from time to time in the Wall Street Journal, from the respective dates of the non-responsible Party’s making of the payment or incurring of the cost and expense, shall constitute either additional Rent payable by the Tenant under this Ground Lease or an offset against rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

 

17


11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Project Site, including without limitation, any liabilities, obligations and/or debts owed to laborers, vendors, brokers, materialmen, and other service providers, and then offset against the Rent any such amount(s) paid by the Tenant.

12. Entry on Premises by Landlord, Etc.

The Landlord and its representatives shall have no right to enter the Project Site, except as specifically authorized from time to time in advance in writing by the Tenant after written notice to Tenant of such request by the Landlord; and such authorization shall be in Tenant’s sole discretion, and if/when granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of Tenant. Such entry on the Project Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions such that access to certain sections of the Project Site will be restricted.

13. Destruction by Fire or Other Casualty.

If the Facility or any Improvements erected on the Project Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the willful misconduct of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Facility or the Improvements. In the event that the Tenant so decides not to restore or reconstruct the Facility or the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove any ruins or rubble remaining on the Project Site at the Tenant’s sole cost and expense.

14. Assignment; Subleasing; Right of First Refusal.

14.1 Restrictions on Landlord. The Landlord shall not assign this Ground Lease or sell the Project Site, in whole or in part, (including without limitation by transfer of control or otherwise) without the prior written consent of the Tenant, which consent shall not be unreasonably withheld, delayed, or conditioned, except with respect to the Tenant’s right of first refusal as set forth in Section 14.3. This Ground Lease shall inure to the benefit of and shall be binding upon the Landlord’s permitted assigns.

 

 

18


14.2 Restrictions on Tenant. Subject to the provisions of Section 23, the Tenant shall not assign this Ground Lease, in whole or in part, without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least thirty (30) days prior written notice of any proposed assignment, together with a copy of the proposed assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing, including to a Leasehold Lender, (ii) to a Leasehold Lender or any purchaser upon a foreclosure of a Leasehold Mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a Leasehold Mortgage, (iii) to any Affiliate or member of the Tenant, (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, or (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder. The Tenant shall not sublease all or any portion of the Project Site without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned.

14.3 Right of First Refusal. During the Initial Term or any Extended Term of this Ground Lease, the Landlord may not transfer a portion of the Project Site and may only transfer the entire Project Site through a bona fide sale in exchange for a sum certain of money. If Landlord, during the Initial Term or any Extended Term of this Ground Lease, receives a Bona Fide Offer from a third party to buy or acquire all or any portion of the Project Site separately or as a part of a larger parcel of which the Project Site is a part, the Landlord will promptly, within ten (10) Business Days of such receipt, give written notice to Tenant of the terms of the Bona Fide Offer made or received, including the cash price attributable to the Project Site. If the sale is a tract of which the Project Site is a part, then the cash price attributable to the Project Site will be that part of the cash price multiplied times a fraction, the denominator of which is the total number of acres in the Project Site and the numerator of which is the total number of acres in the larger tract to be sold. The notice shall also state the other terms and conditions of the proposed sale and the Landlord’s willingness to sell for that cash price and on those terms. Upon receiving the notice, the Tenant may exercise the right, in the manner specified below, to purchase either the property described in the Bona Fide Offer or the Project Site (or part thereof) at the stated cash price in the Bona Fide Offer. This Section 14.3 does not apply to transfers pursuant to successions or donations executed in accordance with Louisiana law.

14.4 Exercise of Right of First Refusal. If the Tenant elects to purchase the property or Project Site described in the Bona Fide Offer under the provisions of Section 14.3, the Tenant must notify the Landlord of such election, doing so in writing delivered to the Landlord within thirty (30) Business Days after the date of the Landlord’s written notice to Tenant of the Bona Fide Offer. If the Tenant elects to refuse the Bona Fide Offer, the Tenant need take no action whatsoever; further, if the Tenant fails to deliver to the Landlord a notice of the Tenant’s election within the time required for such notice, the Tenant will be deemed to have refused the Bona Fide Offer. If the Tenant refuses, or is deemed to have refused, the Bona Fide Offer, the Landlord is free to sell the property pursuant to the Bona Fide Offer subject to this Ground Lease and any Leasehold Mortgage, any New Lease and any Non-Disturbance Agreement, and continuation of the leasehold interest created by this Ground Lease and any New Lease.

14.5 Continuation of Right. If for any reason the Project Site is not sold by the Landlord following a Bona Fide Offer from a third party, the right of first refusal granted and described in the preceding Sections 14.1 through 14.4 shall continue in full force and effect, on the same terms and conditions.

 

19


15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of fifteen (15) days after written notice thereof from the Landlord to the Tenant.

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15.1(a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Project Site or discharge from the Project Site shall not constitute an Event of Default.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages; Termination. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default, the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the Tenant shall be liable for such reasonable damages unless such Event of Default is reasonably remedied in a timely manner and all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default, together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and payable, and all costs and expenses reasonably incurred by or on behalf of the Landlord as a result of the Event of Default, including reasonable attorneys’ fees, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective and is not valid if the Landlord does not give prior written notice to the Tenant pursuant to Section 15.1.

 

20


(b) Landlord’s Right to Cure Tenant’s Event of Default. Upon the occurrence of an Event of Default of the Tenant which is not cured or having commenced curing by the Tenant within sixty (60) days as provided in Section 15.2(b), then, subject to the prior written consent of any Leasehold Lender under Section 23, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others to cure the Event of Default. The Tenant shall be responsible for all costs, including attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord.

15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Project Site to the Landlord, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Project Site and may have, hold, and enjoy the Project Site; and (ii) all obligations of the Tenant hereunder for additional rent or any portion thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. In the event of any termination, the Landlord shall be under a duty to seek a successor tenant. If the Landlord obtains a successor tenant during what would have been the remainder of the term of this Ground Lease, the Tenant shall receive a credit for rentals collected from said successor tenant for the remaining term of this Ground Lease. If no successor tenant is obtained, the Tenant shall be liable for Rent obligations otherwise provided for in this Ground Lease.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Project Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

16. Events of Default of the Landlord.

16.1 Landlord’s Event of Default; Right to Cure. Any failure of the Landlord to perform and/or to comply with any of its obligations, covenants, agreements, terms, or conditions contained in this Ground Lease shall constitute a “Landlord’s Event of Default” hereunder. The Landlord shall have sixty (60) days after notice by the Tenant to the Landlord of Landlord’s Event of Default to fully cure Landlord’s Event of Default.

16.2 Tenant’s Remedies; Cure. In the event of a Landlord’s Event of Default that is not fully cured under Section 16.1, in addition to all other remedies available to the Tenant, the Tenant may cancel this Ground Lease by written notice to the Landlord. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such

 

21


matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof, and shall be immediately payable to the Tenant. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default that is not fully cured under Section 16.1.

16.3 Tenant’s Right to Cure Landlord’s Event of Default. Upon the occurrence of a Landlord’s Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord’s Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others, purchasing the required goods or services and procuring necessary insurance. The Landlord shall be responsible for all costs including attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

17. Mutual Obligations.

17.1 Late Charges; Interest. If any Rent or other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of ten (10) days after receipt of written notice, such sum shall bear a late charge equal to one percent (1.0%) of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise (excluding, however, specific performance against the Tenant) and the exercise or beginning of the exercise by the Parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

 

22


18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by United States registered or certified mail, return receipt and signature requested, postage prepaid, to the Parties at the following numbers and addresses:

 

To the Tenant:

  

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North

Suite 1500

Arlington, VA 22209

Attention: General Counsel

Telephone: [***]

Email: [***]

With a copy to:

  

[***]

Norman Business Law Center

145 East Street

Lake Charles, LA 70601

Telephone: [***]

Facsimile: [***]

Email: [***]

To the Landlord:

  

JADP Venture, LLC

602 West Prien Lake Road, #131

Lake Charles, LA 70601

Attention: [***]

Email: [***]

With a copy to:

  

Stockwell, Sievert, Viccellio, Clements &

Shaddock, LLP

P.O. Box 2900

Lake Charles, LA 70602-2900

Attention: [***]

Telephone: [***]

Email: [***]

or to such other numbers or addresses as either above designated recipients may from time to time designate by written notice to the other designated recipient hereto at least fifteen (15) days in advance of an effective date stated therein.

 

23


18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mail, return receipt and signature requested, postage prepaid.

19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable possession of the Project Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Project Site during the Initial Term, any Extended Term and the Removal Period of this Ground Lease without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord. This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow compatible use of the remainder of their property adjacent to the Project Site and, other than the existing sewage pond adjacent to the Project Site and the existing tower located on the Project Site pursuant to the terms of the Tower Lease, will not create or allow the creation of a visual, olfactory or auditory nuisance on said remainder of their property. Unless prior written consent is received from the Tenant, such consent not to be unreasonably withheld, the Landlord shall not cause the terms of the Tower Lease to be amended, modified, altered or changed in any respect.

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that: (i) it is the sole owner of good title to all of the Project Site; (ii) the Project Site is subject to no Liens, privileges, encumbrances, defects in title, servitudes, easements, restrictions, dedications, leases, mineral leases, reservations or other exceptions to title; (iii) during the term hereof it shall not encumber the Project Site; (iv) it is authorized to make this Ground Lease for the term hereof; (v) the provisions of this Ground Lease do not and will not conflict with or violate any of the provisions of existing agreements between the Landlord and any third party; and (vi) the Landlord will deliver the Project Site free of all tenants and occupants and claims thereto.

20. Eminent Domain.

20.1 Complete Condemnation. If, during the term hereof, the whole of the Project Site shall be taken under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking) by any public or private authority, then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided that the Tenant shall share in the condemnation award as provided herein. The Tenant may continue to occupy the Project Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Project Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Project Site from and after the date of such taking.

 

24


20.2 Partial Condemnation. If, during the term hereof, any public or private authority shall, under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking), makes a taking resulting in the reduction of the surface area of the Project Site by fifteen percent (15%) or more, or of fifteen percent (15%) or more of the value of the Facility, the Improvements or the Landlord’s Improvements, or resulting in material interference to the Project or the Tenant’s ability to use in a commercially reasonable manner the remainder of the Project Site, the Facility, the Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of the exercise of its election within one-hundred twenty (120) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2, the term hereof shall cease and terminate as of the last day of the calendar month in which such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall not be refunded to the Tenant, and the Tenant shall share in the condemnation award as provided herein.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the term hereof shall continue in full force and effect, and the Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete taking pursuant to Section 20.1, the Tenant will be entitled to receive the portion of the condemnation award (or settlement) attributable to (i) the value of the Facility and Improvements and Landlord’s Improvements, and fixtures and other property located on the Project Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Project Site so taken, plus (iii) other compensation or benefits paid as a consequence of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking (if any such compensation or benefits are paid by the applicable taking authority) and the Landlord shall be entitled to recover that portion of the condemnation award (or settlement) fairly attributable to the value of the land taken. In the event Tenant’s Property, the Improvements or the Facility are not taken, the Tenant shall not be entitled to any portion of the award, and in the event no Landlord’s property is taken, the Landlord shall not be entitled to any portion of the award. In the event of a partial taking of the Improvements, Tenant’s Property and/or Facility, the entire award or settlement shall be paid to the Tenant. In the event of a partial taking of the Project Site, the Tenant will be entitled to receive the portion of the award attributable to (i) the value of the portion of the Facility, Improvements and Tenant’s Property located in the portion of the Project Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Project Site so taken, plus (iii) damage to the remaining Facility, and the Tenant will promptly restore the remaining portion of the Facility to the extent of the award payable to the Tenant. Nothing contained herein shall prohibit the Tenant’s claiming relocation damages or damages for lost profits or loss of leasehold advantage against the taking authority in any appropriate proceeding.

 

25


21. Temporary Taking or Other Deprivation.

If, during the term hereof, (i) less than all of the Landlord’s title to all or any portion of the Project Site is taken for temporary use or occupancy, or (ii) any public or private authority takes any action not resulting in a taking of all or any portion of the Project Site but resulting in a right to compensation therefor, such as changing of the grade of any street upon which the Project Site abuts, then, except as otherwise provided in Section 20, the Tenant shall be entitled to make claim for, recover, and retain all awards, whether pursuant to judgment, agreement, or otherwise, recoverable in connection therewith.

22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure; provided that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section shall govern and control.

23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Project Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage, or any agent or trustee therefor, that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant. The term “Leasehold Mortgage” shall mean, at any point in time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Project Site and this Ground Lease. It is acknowledged and agreed that, during the term of this Ground Lease, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the term of this Ground Lease, the Tenant shall provide the Landlord with written notice of the identity, contact information and address for each Leasehold Lender (or the agent authorized to act on behalf of the Leasehold Lender), such notice to be provided to the Landlord by the Tenant within no less than a calendar year within which the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

 

26


23.2 Right to Perform for Tenant; Right to Cure.

(a) In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and Landlord shall accept such performance by Leasehold Lender with the same force and effect as if furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing.

(b) If any default in the performance of an obligation of the Tenant under this Ground Lease is not susceptible to being cured by Leasehold Lender, the Landlord shall have no right to terminate this Ground Lease with respect to such default and such default shall be deemed waived for the benefit of Leasehold Lender only; provided that:

(i) Leasehold Lender shall have commenced to cure (i) any other non-payment default of the Tenant that is susceptible to being cured by Leasehold Lender and (ii) any default in the payment of any portion of Rent, in each case, within the time periods prescribed under Section 23.2(a);

(ii) The Leasehold Lender (or its designee) shall have commenced to acquire the Tenant’s interest in this Ground Lease and the Project Site or to commence foreclosure or other appropriate proceedings under the Leasehold Mortgage within the time periods prescribed under Section 23.2(a);

(iii) if Leasehold Lender (or its designee) shall acquire the Tenant’s interest in this Ground Lease and/or the Project Site, Leasehold Lender (or its designee) shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition; and

(iv) if any third party shall, by foreclosure or dation en paiement under the Leasehold Mortgage or by assignment or other transfer from Leasehold Lender, acquire the Tenant’s interest in and to the Project Site under this Ground Lease, such third party shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by a third party with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition.

 

27


However, if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then notwithstanding any provision in this Section 23 to the contrary, the Landlord may exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’s prior written consent, and any such action taken without Leasehold Lender’s consent shall not be binding on the Tenant or Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.4 Delivery of Notices. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including, without limitation, any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been delivered to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in writing to the Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Project Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’s interests in the Project Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including, without limitation, the acquisition of the Tenant’s interest in this Ground Lease and the Project Site created thereby in a transaction described in this Section 23 or the taking of possession of the Project Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no

 

28


personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender; provided that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Project Site.

23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2, the purchaser at any sale of this Ground Lease and the interests in and to the Project Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including, without limitation, power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Project Site thereby created under any instrument of assignment or transfer in lieu of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Project Site thereby created.

23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, substantially all, or any part of the Project Site or the Tenant’s Facility. Rent shall continue to be due and payable as set forth in this Ground Lease.

23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent domain proceeding of all, substantially all, or any part of the Project Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Facility, the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Project Site created by this Ground Lease and the value of the leasehold improvements located on the Project Site, up to an amount equaling the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the

 

29


terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Facility and/or the Tenant’s interest in, under and to this Ground Lease; provided that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under applicable law to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this Ground Lease. In the event of a taking of a portion of the Project Site, the Rent shall be reduced pro rata based upon the portion of the Project Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease.

23.9 New Direct Lease.

(a) If this Ground Lease is canceled or terminated for any reason (except in connection with a Bankruptcy Proceeding, for which the provisions of Section 23.10 are hereby agreed upon by the Landlord and the Tenant), and provided that Leasehold Lender has (i) commenced to cure and continues diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, and (ii) cured any payment default in respect of any portion of Rent, the Landlord hereby agrees that the Landlord shall, upon Leasehold Lender’s written election within one hundred twenty (120) days of such cancellation or termination, promptly enter in a new, direct lease with Leasehold Lender (or its nominee or any other party which Leasehold Lender may designate, including without limitation, the Tenant) with respect to the Project Site on the same terms and conditions as this Ground Lease (a “New Lease”), it being the intention of the parties to preserve this Ground Lease and the interests in and to the Project Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Said New Lease shall be superior to all rights, liens and interests intervening between the date of this Ground Lease and the granting of the New Lease and shall be free of any and all rights of the Tenant under this Ground Lease.

(b) The Tenant and the Landlord acknowledge and agree that Leasehold Lender shall have the right to encumber such direct New Lease and the estate created thereby with a deed of trust or a mortgage (as the case may be) on the same terms and with the same lien priority as the Leasehold Mortgage, it being the intention of the parties to preserve the priority of the Leasehold Mortgage, this Ground Lease and the interests in and to the Project Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. If this Ground Lease is rejected, cancelled or terminated for any reason and Leasehold Lender, its nominee or a designee of Leasehold Lender enters into a direct lease with the Landlord with respect to the Project Site, the Landlord hereby agrees that it will execute such documents as Leasehold Lender may require in order to ensure that the new direct lease provides for customary leasehold mortgagee protections, including without limitation, protections similar to those contained herein.

23.10 Bankruptcy. In the event of a proceeding under the United States Bankruptcy Code (Title 11 U.S.C.) as now or hereafter in effect (a “Bankruptcy Proceeding”):

 

30


(a) If this Ground Lease is rejected in connection with a Bankruptcy Proceeding by the Tenant or a trustee in bankruptcy (or other party to such proceeding) for the Tenant, such rejection shall be deemed an assignment by the Tenant to the Leasehold Lender of the Tenant’s Property and all of the Tenant’s interest under this Ground Lease, and this Ground Lease shall not terminate and the Leasehold Lender shall have all rights and obligations of the Tenant as if such Bankruptcy Proceeding had not occurred, unless Leasehold Lender shall reject such deemed assignment by notice in writing to the Landlord within thirty (30) days following rejection of this Ground Lease by the Tenant or the Tenant’s trustee in bankruptcy. If any court of competent jurisdiction shall determine that this Ground Lease shall have been terminated notwithstanding the terms of the preceding sentence as a result of rejection by the Tenant or the trustee in connection with any such proceeding, the rights of Leasehold Lender to a New Lease from the Landlord pursuant to Section 23.9 hereof shall not be affected thereby.

(b) In the event of a Bankruptcy Proceeding against the Landlord:

(i) If the bankruptcy trustee, the Landlord (as debtor-in-possession) or any party to such Bankruptcy Proceeding seeks to reject this Ground Lease pursuant to United States Bankruptcy Code §365(h)(1), the Tenant shall not have the right to treat this Ground Lease as terminated except with the prior written consent of Leasehold Lender and the right to treat this Ground Lease as terminated in such event shall be deemed assigned to Leasehold Lender, whether or not specifically set forth in the Leasehold Mortgage, so that the concurrence in writing of the Tenant and the Leasehold Lender shall be required as a condition to treating this Ground Lease as terminated in connection with such Bankruptcy Proceeding.

(ii) Unless this Ground Lease is treated as terminated in accordance with Section 23.10(b)(i), then this Ground Lease shall continue in effect upon all the terms and conditions set forth herein, including Rent, but excluding requirements that are not then applicable or pertinent to the remainder of the term of this Ground Lease. Thereafter, the Tenant or its successors and assigns shall be entitled to any offsets against Rent payable hereunder for any damages arising from such bankruptcy, to the extent the Tenant’s operation of business has been materially interfered with, and any such offset properly made shall not be deemed a default under this Ground Lease. The lien of the Leasehold Mortgage shall extend to the continuing possessory rights of the Tenant following such rejection with the same priority as it would have enjoyed had such rejection not taken place.

23.11 Estoppel Certificates; Non-Disturbance Agreements.

(a) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel”) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under this Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant

 

31


thereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that each of this Ground Lease and the Non-Disturbance Agreement, true, correct copies of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, have not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Project Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Landlord’s power and authority to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Project Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Project Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, and any Non-Disturbance Agreement, there do not exist any other agreements concerning the Project Site or this Ground Lease, whether oral or written, to which Landlord is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Project Site, other than those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the Landlord Estoppel, the present lessor under this Ground Lease and owns good and indefeasible title to the Project Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Project Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Project Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Project Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (xix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

(b) Within fifteen (15) days following Leasehold Lender’s or the Landlord’s written request, the Tenant shall provide Leasehold Lender with an estoppel certificate (the “Tenant Estoppel”) which shall certify to such requesting Leasehold Lender (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Landlord of any other conditions under this Ground Lease, or alternatively, as

 

32


to the full satisfaction and compliance by the Landlord of any other conditions required under this Ground Lease, (iii) as to any existing default of the Landlord under this Ground Lease, or alternatively that the Landlord is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Landlord hereunder, and as to any existing event or condition in existence as of the date of the Tenant Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Tenant to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Tenant, (v) that this Ground Lease, a true and correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Project Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Tenant’s power and authority to execute the Tenant Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Tenant asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Project Site, (x) as to any written notice received by the Tenant from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Project Site, (xi) that there are no fees, rents, royalties, or other sums, whether or not constituting rent, due and owing as of the date of the Tenant Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, there do not exist any other agreements concerning the Project Site or this Ground Lease, whether oral or written, to which the Tenant is a party (other than those set forth on a schedule to the Tenant Estoppel), (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Project Site, other than those set forth on a schedule to the Tenant Estoppel, (xiv) that the Tenant is, as of the date of the Tenant Estoppel, the present lessee under this Ground Lease and holds a valid leasehold interest in the Project Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Tenant has not assigned, sublet, hypothecated, leased, or otherwise transferred it interests, or any portion thereof, in and to the Project Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Tenant’s interest in the Project Site, other than those set forth on a schedule to the Tenant Estoppel, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Tenant is a party or by which the Tenant is otherwise bound affecting the Tenant’s interest in and to the Project Site, (xvii) that the Tenant has not commenced any action or sent any notice to the Landlord for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Tenant is not, as of the date of the Tenant Estoppel, entitled to terminate, cancel, modify, or surrender this Ground Lease, and (xviii) as to such other matters related to this Ground Lease as such Leasehold Lender may reasonably determine from time to time.

(c) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall enter into a non-disturbance agreement with Leasehold Lender or its designee, in the form attached hereto as Exhibit 5 (a “Non-Disturbance Agreement”).

 

33


23.12 No Termination by Confusion. There shall be no termination by confusion of this Ground Lease or any interest in this Ground Lease or of the interests in and to the Project Site created thereby, by reason of the fact that this Ground Lease or such interest therein may be directly or indirectly owned by any person who shall hold any ownership interest in the Project Site, nor shall there be such a termination by confusion by reason of the fact that all or any part of the interests in and to the Project Site created by this Ground Lease may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any ownership interest in the Project Site or any ownership interest of the Landlord under this Ground Lease.

23.13 Landlord’s Recognition of Tenant. Landlord hereby recognizes Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that Tenant acquired its interest in this Ground Lease and in and to the Project Site in accordance with the terms of this Ground Lease.

23.14 Agreement to Amend. The Landlord recognizes the importance of the Tenant’s ability to obtain Leasehold Mortgages, and that the provisions of this Ground Lease may be subject to the approval of a Leasehold Lender. If any Leasehold Lender should require, as a condition to such financing, any reasonable modifications of this Ground Lease, whether for purposes of clarifying the provisions of this Ground Lease or to include provisions then customary for leasehold financing transactions, the Landlord agrees to execute the appropriate amendments to this Ground Lease; provided, however, that no such modification shall, to the detriment of the Landlord, impair any of the Landlord’s rights, as reasonably determined by the Landlord or increase any of the Landlord’s obligations, as reasonably determined by the Landlord, under this Ground Lease.

23.15 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

23.16 Subordination of Landlord’s Lien. The Landlord hereby subordinates any lien or privilege it may have on any movables found from time to time in or upon the Project Site, including without limitation, the Landlord’s privileges pursuant to La. Civil Code articles 2707, et seq., to any Leasehold Lender’s rights under this Section 23 and the lien of any Leasehold Mortgage.

24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

24.2 Successors. The covenants, agreements, terms, provisions, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties hereto.

 

34


24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

24.6 No Oral Change or Termination. This Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties hereto with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, including the Original Ground Lease, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

24.9 Litigation. In case of any litigation between the Parties hereto regarding the subject matter hereof, the losing Party shall pay all reasonable costs and expenses (including reasonable attorneys’ fees) of the prevailing Party. The venue of any litigation shall be solely in Calcasieu Parish.

 

35


24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

24.11 Authority. Each of the Landlord and the Tenant represents and warrants that it has the authority to enter into this Ground Lease, that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date, (a) the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 3, evidencing its authority to execute and perform under this Ground Lease and (b) the Landlord shall deliver to the Tenant a resolution in the form attached hereto as Exhibit 4, evidencing its authority to execute and perform under this Ground Lease.

24.12 Brokers and/or Real Estate Agents. Each of the Landlord and the Tenant represents, acknowledges and agrees that it is not represented by any real estate broker/agent and that it is not responsible for payment of any other commissions to any real estate brokers/agents in connection with this Ground Lease.

24.13 Legal Relationships; Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. There is no third party beneficiary of this Ground Lease, except as provided in Section 23.15 and any rights of a Leasehold Lender as provided herein. This Ground Lease is the product of the Parties joint negotiation and equal drafting thereof. The language of this Ground Lease shall be construed as a whole according to its fair meaning and not construed strictly for or against any of the Parties pursuant to any statue, case law or rule of interpretation or construction to the contrary.

24.14 Settlement Funds. The Landlord and the Tenant agree that any claims, which may exist for damage to the Project Site, exclusive of any improvements of the Tenant, shall be reserved to the sole benefit of the Landlord. Similar claims that may exist for damage to Tenant improvements and/or operations shall be reserved to the sole benefit of the Tenant.

24.15 Limited Recourse. The Landlord agrees that the sole recourse of the Landlord for any damages or liabilities due by the Tenant hereunder shall be limited to the assets of the Tenant, without recourse individually or collectively to the members or the Affiliates of the Tenant, the Leasehold Lenders or their respective directors, officers, agents, members, shareholders, managers, partners, employees or representatives.

24.16. Further Assurances. In connection with this Agreement and the transactions contemplated hereby, each Party shall execute and deliver any additional documents and instruments and perform any additional acts that may be necessary or appropriate to effectuate and perform the provisions of this Agreement and those transactions, including in connection with the requests of any Financing Parties or Leasehold Lender.

 

36


24.17 No Waiver or Surrender. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Project Site and no agreement to accept a surrender of the Project Site shall be valid unless it is in writing and signed by the Landlord.

24.18 Memorandum of Lease. The Parties hereto agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’s interest hereunder; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease.

[Remainder of page left intentionally blank; signatures on following pages]

 

37


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

    

LANDLORD:

 

/s/ Brenda Ulmer

           JADP VENTURE, LLC
WITNESS Brenda Ulmer     
     By: /s/ E. Scott Henry         

/s/ Marcela Lemoine

     Name: E. Scott Henry
WITNESS Marcela Lemoine      Title:  Manager

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Calcasieu and State of Louisiana, personally came and appeared E. Scott Henry, who, after being sworn by me, did execute this agreement on the 12th day of July, 2019 at Lake Charles, State of Louisiana.

   /s/ Alan McColl   

NOTARY PUBLIC

 

          

TENANT:

 

/s/ John Thompson

      VENTURE GLOBAL CALCASIEU PASS, LLC
WITNESS John Thompson      
      By: /s/ Keith Larson         

/s/ Ben Davidson

      Name: Keith Larson
WITNESS Ben Davidson       Title:  Secretary

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 15th day of July, 2019 at Arlington, State of Virginia.

   /s/ Annette B. Thrasher   

NOTARY PUBLIC

 

1


Exhibit 1-A    Legal Description of Project Site
Exhibit 1-B    Project Site Survey
Exhibit 2    Project and Facility Description
Exhibit 3    Tenant’s Resolution
Exhibit 4    Landlord’s Resolution
Exhibit 5    Form of Non-Disturbance Agreement

 

39


EXHIBIT 1-A

LEGAL DESCRIPTION OF THE PROJECT SITE

PARCEL “C”

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND A HALF INCH DIAMETER IRON PIPE; THENCE S.00°36’56”W., A DISTANCE OF 4,956.53 FEET TO A POINT ALONG THE EAST LINE OF SECTION 36, TOWNSHIP 15 SOUTH, RANGE 10 WEST; THENCE S.00°35’10”W., A DISTANCE OF 1,619.34 FEET ALONG THE EAST LINE OF SECTION 37, TOWNSHIP 15 SOUTH, RANGE 10 WEST TO A POINT BEING MARKED BY A FOUND 4” TRANSITE PIPE; SAID POINT BEING THE POINT OF BEGINNING; THENCE N.89°24’41”W., A DISTANCE OF 1,321.14 FEET TO A POINT BEING MARKED BY A FOUND 1.25” DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 885.47 FEET TO A FOUND 1.25” DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 732.98 FEET TO A POINT BEING MARKED BY A FOUND 1.25” DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 676.76 FEET TO A POINT BEING MARKED BY A FOUND 1.25” DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 59.94 FEET TO A POINT BEING MARKED BY A FOUND 1.25” DIAMETER IRON PIPE, OFFSET 59.94 FEET S.00°36’56”E. OF TRUE POSITION; THENCE N.00°36’56”E, A DISTANCE OF 284.89 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; THENCE N.89°27’01”E., A DISTANCE OF 201.04 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; THENCE S.89°27’01”E., A DISTANCE OF 1,119.26 FEET TO A POINT BEING MARKED BY A FOUND 4” DIAMETER TRANSITE PIPE; THENCE N.00°36’56”E., A DISTANCE OF 728.99 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE, OFFSET 63.05 FEET S.00°36’56”W. OF TRUE POSITION; THENCE N.78°16’30”E., A DISTANCE OF 668.32 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE, OFFSET 49.96 FEET S.01°12’05 ”W. OF TRUE POSITION; THENCE S.01°12’05”W., A DISTANCE OF 722.21 FEET TO A POINT BEING MARKED BY A FOUND 4” DIAMETER IRON PIPE; THENCE S.01°17’48”W., A DISTANCE OF 160.02 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE;

 

40


THENCE S.32°00’12”E., A DISTANCE OF 170.32 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; THENCE S.89°20’36”E., A DISTANCE OF 950.02 FEET TO A POINT BEING MARKED BY A FOUND 2” DIAMETER IRON PIPE; THENCE S.01°26’04”W., A DISTANCE OF 1,126.85 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; THENCE S.01°26’04”W ., A DISTANCE OF 1,126.85 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; THENCE S.01°26’04”W., A DISTANCE OF 1,126.85 FEET TO A POINT, ALONG THE NORTH LINE OF LAND CLAIMED BY THE STATE OF LOUISIANA, BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; THENCE S.81°00’02”W., A DISTANCE OF 384.49 FEET TO A POINT, ALONG THE NORTH LINE OF LAND CLAIMED BY THE STATE OF LOUISIANA, BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; THENCE S.81°00’02”W., A DISTANCE OF 637.07 FEET TO A POINT, ALONG THE NORTH LINE OF LAND CLAIMED BY THE STATE OF LOUISIANA, BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; THENCE S.81°00’02”W., A DISTANCE OF 637.07 FEET TO A POINT, ALONG THE NORTH LINE OF LAND CLAIMED BY THE STATE OF LOUISIANA, BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; THENCE N.00°34’10”E., A DISTANCE OF 12.23 FEET TO A FOUND 1.25” DIAMETER IRON PIPE; THENCE N.00°34’10”E., A DISTANCE OF 1,158.58 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 9,952,202.34 SQUARE FEET OR 228.4711 ACRES, MORE OR LESS, IS SITUATED IN SECTIONS 36 & 37, TOWNSHIP 15 SOUTH, RANGE 10 WEST & SECTIONS 4 & 5, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “C” ON THE HERE TO ATTACHED PLAT.

 

41


EXHIBIT 1-B

SURVEY MAP OF PROJECT SITE

[Omitted]


EXHIBIT 2

PROJECT AND FACILITY DESCRIPTION

[Omitted]


EXHIBIT 3

TENANT’S RESOLUTION

[Omitted]


EXHIBIT 4

LANDLORD’S RESOLUTION

[Omitted]


EXHIBIT 5

FORM OF NON-DISTURBANCE AGREEMENT

[Omitted]

Exhibit 10.52

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

FIRST AMENDMENT TO AMENDED AND

RESTATED GROUND LEASE AGREEMENT

(168 Acres)

THIS FIRST AMENDMENT TO AMENDED AND RESTATED GROUND LEASE AGREEMENT (the “Amendment”) is executed and effective as of the 12th day of December 2023, by and between Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Tenant”), and JADP Venture, LLC, a Louisiana limited liability company (the “Landlord”).

BACKGROUND

 

A.

The Landlord and the Tenant entered into that certain Ground Lease Agreement dated as of March 14, 2019 (the “Original Lease”) for the lease of certain immovable property and certain water and surface and subsurface land rights situated in Cameron Parish, Louisiana, which comprises approximately two hundred twenty-eight (228) acres (the “Original Site”).

 

B.

Landlord and Tenant executed that certain Notice of Ground Lease with Right of First Refusal (the “Original Notice”), dated as of March 14, 2019, recorded on March 20, 2019, as Instrument Number 345000 in the official records of Cameron Parish, in respect of the Original Lease.

 

C.

Landlord and Tenant further executed that certain Amended and Restated Notice of Ground Lease with Right of First Refusal, dated as of March 25, 2019, recorded on March 26, 2019, as Instrument Number 345049 in the official records of Cameron Parish, in order to correct typographical errors contained in the Original Notice.

 

D.

Landlord and Tenant amended and restated the Original Lease in its entirety pursuant to an Amended and Restated Ground Lease, dated as of July 15, 2019 (the “Amended and Restated Lease”) pursuant to which, Tenant leased the Original Site from Landlord and Landlord has also granted to Tenant a right of first refusal to purchase the Original Site upon the amended and restated terms and conditions as more fully described therein.

 

E.

Landlord and Tenant further executed that certain Second Amended and Restated Notice of Ground Lease Agreement with Right of First Refusal (the “Second A&R Notice”), dated as of July 15, 2019, recorded on August 9, 2019, as Instrument Number 346079 in the official records of Cameron Parish, which was recorded in order that third parties may have notice of Tenant’s right of first refusal pursuant to the Amended and Restated Lease.

 

F.

Landlord and Tenant further executed that certain Third Amended and Restated Notice of Ground Lease Agreement with Right of First Refusal (the “Third A&R Notice”), dated as of August 14, 2019, recorded on August 14, 2019, as Instrument Number 346122 in the official records of Cameron Parish, which was recorded in order that third parties may have notice of Tenant’s and Landlord’s addresses.

 

G.

Landlord and Tenant desire to amend the Amended and Restated Lease as set forth below to remove and release certain immovable property leased by Tenant and revise the rent.

 

1


AGREEMENT

In consideration of the mutual covenants and agreements set forth herein, and other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, Landlord and Tenant hereby amend the Amended and Restated Lease as follows:

 

1.

Amendments.

 

  (a)

Exhibit 1-A and Exhibit 1-B of the Amended and Restated Lease are hereby amended by replacing Exhibit 1-A and Exhibit 1-B of the Amended and Restated Lease in their entirety with Exhibit 1-A and Exhibit 1-B attached hereto.

 

  (b)

The first sentence of Section 4.1 of the Amended and Restated Lease is hereby amended such that commencing upon the effective date of this Amendment, the initial rent for the Project Site (“Rent”) shall be [***] per annum, payable in equal installments of [***] per month, adjusted upward on March 14, 2024 and every five (5) years thereafter during the Initial Term and during any Extended Term by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment during any Adjustment Period (as defined below) of greater than [***].

 

  (c)

References to “228 acres” and “two hundred-twenty eight (228) acres” in the Amended and Restated Lease are hereby amended to “168 acres” and “one hundred sixty-eight (168) acres,” respectively.

 

  (d)

The definition of “Survey Map” is deleted and replaced with the following: ““Survey Map” means the ALTA survey of the Project Site, dated October 2, 2023, by Lonnie G. Harper & Associates, Inc., attached as Exhibit 1-B”.

 

2.

Extent of Amendments and References. Except as expressly amended herein, the Amended and Restated Lease shall remain unchanged and in full force and effect.

 

3.

Definitions. Terms defined in the Amended and Restated Lease shall have the same meaning in this Amendment unless defined herein to the contrary.

 

4.

Governing Law. This Amendment shall be governed by and construed in accordance with the laws of the State of Louisiana.

 

2


5.

Counterparts. This Amendment may be executed in one or more counterparts, all of which shall be deemed an original.

[Remainder of page left intentionally blank; signatures on following pages]

 

3


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

TENANT:          
     WITNESSES:
VENTURE GLOBAL CALCASIEU     
PASS, LLC     

/s/ T.A. Wren

a Delaware Limited Liability Company      Print Name: T.A. Wren
By:  

/s/ Keith Larson

    

/s/ J. Layman

Name:   Keith Larson      Print Name: J. Layman
Title:   Secretary     

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 6th day of December, 2023 at Arlington, State of Virginia.

 

/s/ Michael E. Millan

NOTARY PUBLIC
Name: Michael E. Millan
Notary No: 7979927
My Commission Expires: 8-31-26

 

1


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

LANDLORD:           WITNESSES:
JADP VENTURE, LLC     

/s/ Mary Ellen Henry

a Louisiana limited liability company      Print Name: Mary Ellen Henry
By:  

/s/ E. Scott Henry

    

/s/ Amy Singer

Name:   E. Scott Henry      Print Name: Amy Singer
Title:   Manager     

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Calcasieu and State of Louisiana, personally came and appeared E. Scott Henry, who, after being sworn by me, did execute this agreement on the 4th day of December, 2023 at Lake Charles, State of Louisiana.

 

/s/ Kathryn G. Matte

NOTARY PUBLIC
Name:
Notary No:
My Commission Expires:

 

1


EXHIBIT 1-A

LEGAL DESCRIPTION OF THE PROJECT SITE

PARCEL “C-1”

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°36’56“W., A DISTANCE OF 4,956.53 FEET TO A POINT ALONG THE EAST LINE OF IRREGULAR SECTION 36, TOWNSHIP 15 SOUTH, RANGE 10 WEST; THENCE S.00°35’10“W., A DISTANCE OF 1,619.34 FEET ALONG THE EAST LINE OF IRREGULAR SECTION 37; TOWNSHIP 15 SOUTH, RANGE 10 WEST TO A POINT; SAID POINT BEING THE POINT OF BEGINNING; THENCE N.89°24’41“W., A DISTANCE OF 1,321.14 FEET TO A POINT; THENCE N.00°36’56“E., A DISTANCE OF 885.47 FEET TO A POINT; THENCE N.00°36’56“E., A DISTANCE OF 732.98 FEET TO A POINT; THENCE N.00°36’56“E., A DISTANCE OF 188.30 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°36’56“E., A DISTANCE OF 488.45 FEET TO A POINT; THENCE N.00°36’56“E., A DISTANCE OF 344.83 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89° 27’ 01“E., A DISTANCE OF 201.04 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°36’56“W., A DISTANCE OF 831.17 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.89°57’00“E., A DISTANCE OF 1,297.30 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.89°57’00“E., A DISTANCE OF 1,498.35 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.01°26’04“W., A DISTANCE OF 481.29 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.01°26’04“W., A DISTANCE OF 1,126.85 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.01°26’04“W., A DISTANCE OF 1,126.85 FEET TO A POINT ON THE NORTH LINE OF LAND CLAIMED BY THE STATE OF LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.81°00’02“W., A DISTANCE OF 384.49 FEET ALONG THE NORTH LINE OF LAND CLAIMED BY THE STATE OF LOUISIANA TO A POINT; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.81°00’02“W., A DISTANCE OF 637.07 FEET ALONG THE NORTH LINE OF LAND CLAIMED BY THE STATE OF LOUISIANA TO A POINT; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.81°00’02“W., A DISTANCE OF 637.07 FEET ALONG THE NORTH LINE OF LAND CLAIMED BY THE STATE OF LOUISIANA TO THE INTERSECTION OF THE WEST LINE OF IRREGULAR SECTION 4, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH LOUISIANA AND SAID NORTH LINE OF LAND CLAIMED BY THE STATE OF LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°34’10“E., A DISTANCE OF 1,170.81 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 7,302,112.92 SQUARE FEET OR 167.6334 ACRES, IS SITUATED IN SECTION 36, TOWNSHIP 15 SOUTH, RANGE 10 WEST, AND SECTIONS 4 & 5, TOWNSHIP 15 SOUTH, RANGE 9 WEST. CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS TRACT “C-1” ON THE HERETO ATTACHED PLAT. SAID PLAT PREPARED BY LONNIE G. HARPER & ASSOCIATES, BEARING LGH FILE NO. 09/7001/2023, AND DATED OCTOBER 2, 2023.

 

6


EXHIBIT 1-B

SURVEY MAPS OF THE PROJECT SITE

[Omitted]

Exhibit 10.53

 

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

STATE OF LOUISIANA

PARISH OF CAMERON

AMENDED AND RESTATED GROUND LEASE AGREEMENT

(264 Acre )

This AMENDED AND RESTATED GROUND LEASE AGREEMENT (this “Ground Lease”) is executed and effective as of June 20, 2019, by and between Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Tenant”) and Henry Venture, LLC, a Louisiana limited liability company (the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Cameron Parish, Louisiana, consisting of two adjacent parcels which collectively comprise approximately two hundred sixty-four (264) acres identified herein as the Project Site and as further defined below; and

WHEREAS, the Tenant is desirous of leasing land owned by the Landlord for the construction and development and operation of a natural gas liquefaction (“LNG”) facility as generally described in Exhibit 2 (the “Facility”) and other uses permitted by this Ground Lease; and

WHEREAS, the Landlord and the Tenant desire to lease such land in order to develop the land with the Facility and thereby create and provide employment opportunities for the inhabitants of Southwest Louisiana, which will add to the welfare and prosperity of the persons residing within the geographic limits of numerous surrounding Parishes and throughout the State of Louisiana; and

WHEREAS, in connection with the foregoing, the Landlord and the Tenant are parties to that certain Ground Lease Agreement, dated as of March 11, 2019 (the “Ground Lease Commencement Date”), as amended by the First Amendment to Ground Lease Agreement, dated as of March 25, 2019 (as amended, the “Original Ground Lease”); and

WHEREAS, the Landlord and the Tenant have agreed to amend and restate the Original Ground Lease in its entirety on the terms and conditions set forth in this Ground Lease; and

WHEREAS, in accordance with the above, the Tenant has executed this Ground Lease and offers fair value to the Landlord as cause and consideration for this Ground Lease; and

NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this Ground Lease, and the Parties herein covenant and agree as follows:


1. Definitions.

As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

Adjustment Period” has the meaning set forth in Section 4.1.

Affiliate” means any Person controlled by, controlling or under common control with the Landlord or the Tenant, as applicable. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of thirty percent (30%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.

Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Project Site.

Bankruptcy Proceeding” has the meaning set forth in Section 23.10.

Bona Fide Offer” has the meaning set forth in Section 14.3.

Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in the State of New York are authorized or required by law to close.

Consumer Price Index” has the meaning set forth in Section 4.2.

Corps” has the meaning set forth in Section 8.3(a).

CPI Adjustment” has the meaning set forth in Section 4.1.

CPI Disagreement Notice” has the meaning set forth in Section 4.2.

CPI Notice” has the meaning set forth in Section 4.2.

CPI Percentage Increase” has the meaning set forth in Section 4.2.

Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments,. orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Law relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

Event of Default” has the meaning set forth in Section 15.1.

 

2


Extended Term” has the meaning set forth in Section 3.2(a).

Facility” has the meaning set forth in the Recitals hereof.

Facility Contractors” means, collectively, the Persons engaged by the Tenant to construct the Facility and/or develop the Project, Project Site and/or Improvements.

Facility Contracts” means, collectively, the contracts entered into by the Tenant in connection with the design, construction, equipment procurement, operation and maintenance of the Facility and/or the Project, Project Site and/or Improvements.

Fair Market Value” means the value determined pursuant to the process set forth in Section 14.5.

Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Project or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders.

First Appraiser” has the meaning set forth in Section 14.5.

Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include, but not be limited to, the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, droughts, floods, washouts, explosions, breakage or accident or necessity of repairs to machinery or equipment or lines of pipe; (ii) weather related events affecting an entire geographic region; (iii) acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, terrorism, discovery of burial grounds or human remains or legally protected artifacts, insurrections or wars; (iv) the failure or interruption of performance by the Tenant’s engineering, procurement and construction contractor or any subcontractors of such contractor to the extent caused by an event of Force Majeure under this Ground Lease; (v) the failure or interruption of performance by the Tenant’s suppliers by reason of such supplier’s valid declaration of an event that would constitute an event of force majeure under the Tenant’s contract with such supplier; (vi) governmental actions such as necessity for compliance with any court order, law, statute, ordinance, regulation, or policy having the effect of law promulgated by a Governmental Authority having jurisdiction, or that restrict the Tenant’s ability to reasonably construct and/or operate the Facility and/or Project or any delay in issuance or effectiveness of any Governmental Approval that has been properly applied for by the Tenant that is required to construct and/or operate the Facility and/or Project.

Governmental Approval” means any authorization, waiver, consent, approval, license, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority.

 

3


Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

Ground Lease” has the meaning set forth in the Preamble hereof.

Ground Lease Commencement Date” has the meaning set forth in the Recitals hereof.

Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

Hazardous Substances Law” means any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including, but not limited to, the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent it relates to the handling of and exposure to hazardous or toxic materials or similar substances.

 

4


Improvements” means any and all improvements made by Tenant, in its sole discretion, to the Project Site, including but not limited to, improvements relating to the loading, unloading, handling, treatment, processing, producing, transporting, distributing, selling, metering and/or storing of (i) natural gas, natural gas liquids, and other natural gas products, derivatives and by-products and (ii) other petroleum and hydrocarbon liquids, gases, products, derivatives and by-products, including but not limited to (A) the importation, regasification, production, exportation, liquefaction, refinement, enhancement, other treatment and transportation (including by ship, pipeline, truck or rail) of LNG, and LNG by-products and additives and (B) the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of any improvements, component parts and other constructions, fixtures, facilities, equipment and/or appurtenances (including natural gas pipelines, natural gas liquids extraction, processing and delivery facilities, acid gas removal units, natural gas liquefaction trains, LNG regasification facilities, and other treatment facilities, cryogenic pipelines, LNG storage tanks, petroleum and other hydrocarbon liquids storage facilities, nitrogen storage and processing facilities, power generation and transmission infrastructure, marine, rail and trucking receipt, delivery and servicing facilities (including piers, marine terminals, bulkheads, wharfs, docks, inlets, wetslips, moonpools, moorings, jetties, and loading and unloading equipment), and other utilities and facilities (including berms, open space, security fencing, control rooms, offices, warehouses, parking and yards), in each case, necessary, ancillary or desirable to the Tenant in connection with the foregoing.

“Initial Term” has the meaning set forth in Section 3.1.

“Initial Parcels Rent” means on the Ground Lease Commencement Date that portion of the monthly payments of Rent equal to [***] as such amount is escalated during the Initial Term and any Extended Term pursuant to Sections 4.1 and 4.2.

“Landlord” has the meaning set forth in the Preamble hereof.

“Landlord Estoppel” has the meaning set forth in Section 23.11(a).

“Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, affiliates, invitees, agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Project Site and/or Landlord’s Improvements.

“Landlord’s Event of Default” has the meaning set forth in Section 16.1.

“Landlord Indemnitee” has the meaning set forth in Section 9.1.

“Landlord’s Improvements” has the meaning set forth in Section 6.1.

“Lease Year” means a period of twelve (12) consecutive full calendar months. The first Lease Year shall begin on the Ground Lease Commencement Date. Each succeeding Lease Year shall commence upon the anniversary of the first day of the previous Lease Year.

“Leasehold Lenders” has the meaning set forth in Section 23.1.

 

5


Leasehold Loan” has the meaning set forth in Section 23.1.

Leasehold Mortgage” has the meaning set forth in Section 23.1.

Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

LNG” has the meaning set forth in the Recitals hereof.

Minerals” has the meaning set forth in Section 8.3(b).

New Lease” has the meaning set forth in Section 23.9(a).

Non-Disturbance Agreement” has the meaning set forth in Section 23.11(c).

Option Agreements” means (i) the Amended and Restated Real Estate Lease Option Agreement between Landlord and Tenant, dated as of November 20, 2014; and (ii) the Real Estate Lease Option Agreement between Landlord and Tenant, dated as of May 19, 2015.

Party” or “Parties” has the meaning set forth in the Preamble hereof.

Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

Project” means the development, permitting, financing, construction, ownership, operation and/or maintenance of the Facility and the Improvements on the Project Site.

Project Site” means the real (immovable) property of approximately two hundred sixty-four (264) acres consisting of two adjacent parcels described in the legal description set forth in Exhibit 1-A, and illustrated by the Survey Maps attached as Exhibit 1-B, including any waterway areas, upon which the Facility and other Improvements will be located and which real (immovable) property is owned by the Landlord.

Property Taxes” means all real (immovable) and personal (movable) property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

 

6


“Removal Period” means the period of time that is required by Tenant remove any and all of Tenant’s Property, including the Facility and/or Improvements, from the Project Site in accordance with Section 7.1.

“Rent” has the meaning set forth in Section 4.1.

“Second Appraiser” has the meaning set forth in Section 14.5.

“Subsequent Parcel Rent” means on the Ground Lease Commencement Date that portion of the monthly payments of Rent equal to [***] per month, as such amount is escalated during the Initial Term and any Extended Term pursuant to Sections 4.1 and 4.2.

“Surface Waiver” has the meaning set forth in Section 8.3(b).

“Survey Map” means each of (i) the map of survey dated August 22, 2014 by Lonnie G. Harper & Associates, Inc., and (ii) the map of survey dated February 10, 2015 by Lonnie G. Harper & Associates, Inc., each attached as Exhibit 1-B.

“Tenant” has the meaning set forth in the Preamble hereof.

“Tenant Estoppel” has the meaning set forth in Section 23.11(b).

“Tenant Indemnitee” has the meaning set forth in Section 9.3.

“Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Project Site by or on behalf of Tenant, including the Facility and any Improvements.

“Third Appraiser” has the meaning set forth in Section 14.5.

2. Ground Lease Premises.

2.1 Date. The date of this Ground Lease is the Ground Lease Commencement Date.

2.2 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of the rents and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does lease to the Tenant and the Tenant hereby leases from the Landlord, the Project Site and Landlord’s Improvements.

2.3 Servitudes. In addition, the Landlord shall without cost to the Tenant, grant from time to time to the Tenant and others designated by the Tenant (including any Affiliate of the Tenant) any easements, servitudes, and rights of way for access and electricity, communications, gas, water, sewer and other utility lines, products and materials from and to the Project Site over land and waterways sufficient to permit the Tenant to accomplish its purposes in connection with the Project.

 

7


3. Term

3.1 Initial Term. The initial term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on the thirtieth (30th) anniversary of the last day of the month immediately preceding the Ground Lease Commencement Date (the “Initial Term”).

3.2 Extensions.

(a) In consideration of and conditioned upon there being no uncured Event of Default on the part of the Tenant at the time an option is exercised, the Landlord hereby grants unto the Tenant the option to lease the Project Site for four (4) additional ten (10) year terms. If the extension option is exercised in accordance with Section 3.2(b), the first of said additional terms shall commence upon the expiration of the Initial Term and extend for a period of ten (10) years and each of said additional terms commencing upon the expiration of the then current additional term and extending for a period of ten (10) years. Each of such additional terms is referred to herein as an “Extended Term”.

(b) The option to extend this Ground Lease of the Project Site as set forth in Section 3.2(a) must be exercised in each case, if at all, by written notice from the Tenant to the Landlord on or before the date that is three (3) months prior to the expiration of the Initial Term or then current Extended Term, as applicable. The failure of the Tenant to timely exercise the first Extended Term or any subsequent Extended Term shall automatically terminate the right of the Tenant to exercise its option to lease the Project Site in any subsequent Extended Term.

(c) All the terms and conditions of this Ground Lease shall be applicable to any Extended Term, and the Rent payable by the Tenant for any Extended Term shall be in accordance with the provisions set forth in Section 4.

4. Rent.

4.1 Rent. Commencing upon the Ground Lease Commencement Date, the initial rent for the Project Site (“Rent”) shall be [***] per annum, payable in equal installments of [***] per month, adjusted upward every five (5) years thereafter during the Initial Term and during any Extended Term by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment during any Adjustment Period (as defined below) of greater than [***]. The period of time from the Ground Lease Commencement Date through March 11, 2024, and each five (5) year period thereafter shall be defined herein as an “Adjustment Period.” Any upward adjustment based on a CPI Percentage Increase (as defined below) to any payment under this Ground Lease shall hereinafter be referred to as a “CPI Adjustment.”

 

8


Such Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month; provided, however, that (a) the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; and (b) the first payment of Rent due upon the commencement of any new Adjustment Period will be owed and paid one month after the commencement of that Adjustment Period, in order to permit the Tenant to calculate the CPI Percentage Increase, as set forth below.

4.2 CPI Adjustment. If CPI Percentage Increase (as defined below) is more than [***] for the relevant Adjustment Period, then the Rent payable during that Adjustment Period shall be adjusted upward by a percentage equal to the CPI Percentage Increase (as defined below) applicable to such Adjustment Period, but not to exceed an adjustment during any Adjustment Period of greater than [***]. The term “Consumer Price Index” shall mean the unadjusted Consumer Price Index for All Urban Workers, U.S. City Average, All Items, 1982-84=100, calculated and published by the United States Department of Labor, Bureau of Labor Statistics. The “CPI Percentage Increase” shall mean, with respect to any Adjustment Period, [***]. For the avoidance of doubt, no CPI Adjustment shall be made to any payment due under this Ground Lease for any Adjustment Period if the result of such CPI Adjustment would be to (i) reduce the amount of such payment to an amount that is less than the amount of such payment due for the immediately preceding Adjustment Period or (ii) to raise the amount of such payment to an amount that is greater than [***]. For illustrative purposes only, [***]. The CPI Percentage Increase for any Adjustment Period shall be calculated by the Tenant, and the Tenant shall deliver written notice to the Landlord describing such calculation in reasonable detail (“CPI Notice”) no later than thirty (30) days after the commencement of any Adjustment Period. If the Landlord disagrees with the Tenant’s calculation of the CPI Percentage Increase, then the Landlord shall deliver to the Tenant written notice, describing the basis for such disagreement in reasonable detail (“CPI Disagreement Notice”), not later than thirty (30) days after delivery of the CPI Notice. If the Landlord fails to deliver a CPI Disagreement Notice within thirty (30) days after delivery of any CPI Notice, then the Landlord shall be conclusively deemed to have agreed with the calculation of the CPI Percentage Increase set forth in such CPI Notice.

 

9


4.3 Due Date. Except as otherwise provided in this Ground Lease, all Rent payments shall be due in advance on the 1st calendar day of each month and payable by the 15th calendar day of each month during the entire term of this Ground Lease. If the 15th calendar day of a month falls on a day that is not a Business Day, then Rent shall be payable by the following Business Day.

4.4 Place of Payment. Except as otherwise provided herein, Rent shall be payable by check or wire transfer at the following address or via wire instructions, or to such other place as the Landlord may specify and the Tenant deem acceptable, as hereinafter provided, from time to time: [***], or in accordance with bank wire instructions of which Landlord shall notify Tenant.

5. Net Lease; Taxes and Utility Expenses.

5.1 Net Lease. This Ground Lease is a net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs, if any, of every kind and nature whatsoever relating to the Project Site except as expressly otherwise provided in this Ground Lease.

5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and license, impact, permit and Governmental Approval fees applicable to the Facility during the term of this Ground Lease.

(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on or related to the Project Site during the term of this Ground Lease. The Landlord shall promptly provide all Property Tax bills to the Tenant when they become available. Upon the latter of (i) one (1) month after receipt of such Property Tax bill from the Landlord and (ii) the due date of any such Property Taxes, the Tenant shall provide the Landlord with reasonable written evidence from the Cameron Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

5.3 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost, electricity, telephone, water, sewerage, gas, and other utility services to the Project Site; provided, however, the Landlord shall cooperate and facilitate at its cost the contracting of any easements, servitudes and/or rights of way, and grant easements, servitudes and rights of way in accordance with Section 2.3, as required by the Tenant for such utility connections and/or services.

6. Tenant and Landlord Improvements.

6.1 Landlord’s Improvements. “Landlord’s Improvements” are any and all improvements to the immovable property of the Project Site and any and all movable property in existence on the Project Site at the time of the Ground Lease Commencement Date. There are no Landlord’s Improvements except for posts or pilings used in prior construction and remnants of tanks holding water/marine life that may be removed by Tenant.

 

10


6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install on the Project Site, the Facility and any Improvements during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. The Tenant shall be permitted to make any changes, improvements or alterations to the Project Site including without limitation the Facility and any Improvements to the Project Site during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. During the term of this Ground Lease, the Tenant has the right to make any changes, alterations, and/or improvements with respect to the Project as long as such changes, alterations and/or improvements comply with Applicable Laws.

6.3 Governmental Approvals. The Landlord will cooperate and assist (and never oppose) the Tenant in obtaining any and all Governmental Approvals deemed necessary by the Tenant for the Facility and all other Improvements to the Project Site, including with respect to Governmental Approvals from the Federal Energy Regulatory Commission and the Department of Energy. The Landlord will hereafter continue to be obligated to execute appropriate documentation to waive its right to require wetlands mitigation to be completed on the Project Site or other real (immovable) property owned by the Landlord, in such form as necessary to allow the Tenant to complete such wetlands mitigation at locations other than other real (immovable) property owned by the Landlord.

6.4 Tenant’s Property. The Tenant’s Property shall at all times be and remain the sole property of the Tenant.

6.5 Maintenance of Improvements.

(a) Tenant’s Obligation to Maintain. During the Initial Term or any Extended Term, as applicable, the Tenant will keep in reasonably good state of repair the Facility, the Improvements, open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Project Site by the Tenant, and the Tenant will, in its sole discretion and cost, repair such property as often as may be necessary in order to keep the Facility and Improvements in reasonably good repair and condition, except as set forth in Section 6.5(b).

(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease, the Landlord has no obligation to maintain the Project Site, Improvements and/or Landlord’s Improvements (if any) during the Initial Term and/or any Extended Term. The Landlord further agrees that there will be no Landlord improvements on the Project Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Project Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

 

11


7. Tenant’s Surrender of Project Site.

7.1 Surrender at End of Ground Lease. Subject to Section 6.4 and subject and subordinate to Section 23 and the rights of any Leasehold Lender under any Leasehold Mortgage, the Tenant shall and will on the last day of the Initial Term, or if extended, on the last day of the Extended Term hereof, surrender and deliver the Project Site to the Landlord, in good condition as is reasonably practicable (except as provided in Section 6.5 or Section 13), excepting normal wear and tear. If this Ground Lease is terminated for any reason or upon the expiration of the Initial Term and/or Extended Term (if extended) of this Ground Lease, the Tenant shall in good faith proceed with (i) any removal of the Facility and any and all Improvements and (ii) restoration, if any, of the Project Site to its condition prior to construction of the Facility and/or Improvements, in accordance with Applicable Laws. The Tenant shall have all access rights to the Project site that are necessary to remove any and all of the Tenant’s Property including the Facility and/or Improvements. The Tenant shall also comply as required by any federal regulations of the Federal Energy Regulatory Commission or any other federal authority with respect to the Facility on the Project Site.

7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date the Tenant shall assume full dominion, control and responsibility for the Project Site, except to the extent specifically provided herein, to the extent provided under LSA - R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real (immovable) or personal (movable) property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its officers, representatives, agents, or employees or the Landlord’s misrepresentations or its breach of or default under this Ground Lease.

7.3 Holding Over. Except for a Removal Period, if the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, and shall not constitute a renewal or extension of the term of this Ground Lease.

8. Use.

8.1 Permitted Uses; Compliance with Laws; Permits. The Tenant may use the Project Site for any and all uses desired by the Tenant in compliance with all Applicable Laws. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the construction and maintenance of the Facility, the Improvements and/or for the Tenant’s use or activities on the Project Site. The Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Project and security of the Project Site, including, but not limited to, the timely filing, implementation, and enforcement of any security plan required by Applicable Laws. Any fine or penalty imposed by any Governmental Authority solely caused by the failure of the Tenant to comply with this provision, including any fine or penalty imposed upon the Landlord as owner of the Project Site as solely caused by the failure of the Tenant to comply with this provision, shall be the sole responsibility of the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall indemnify and hold harmless the Landlord from the payment of any such fine or penalty, and the Tenant may pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord.

 

12


8.2 Use of Water Frontage. The Tenant shall have any and all rights, including without limitation any and all riparian rights, to use any and all of the water frontage and water bottom of the Project Site, including without limitation, the Landlord’s Improvements (if any) and the area between the water frontage of the Project Site to the Ship Channel and/or the area between the water frontage of the Project Site to the Gulf of Mexico, for mooring of vessels and/or for any and all other uses allowed under Applicable Laws; and the Landlord shall not have the right to use the water frontage of the Project Site, including without limitation all aforementioned areas, for mooring of vessels or any other uses without the prior written consent of the Tenant. It is expressly understood that the Tenant’s consent shall be given or withheld in the Tenant’s sole discretion, and if granted, would be in accordance with any security plan of the Tenant.

8.3 Dirt Moving Activities; Permits; Timber.

(a) The Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Project Site, to the Project Site, and from portions of the Project Site to other portions of the Project Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Project Site and may do so in its discretion. The Tenant shall have the right to remove soil and spoil from, and to add fill to, the Project Site and to dredge the slip and turning basin and dredge and widen the Calcasieu Ship Channel, and deposit the dredge spoils on the Project Site (as allowed by Applicable Laws), in each case in connection with the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of the Facility, and for the purpose of constructing, creating, expanding, operating and maintaining a marine terminal and ship turning basin. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Project Site, including without limitation, for any Improvements, reclamation of lands, erosion control, attainment of spoil, easements/servitudes and/or rights of way; provided that all costs associated with such efforts shall be the responsibility of the Tenant. Except only as provided in Section 8.3(b), the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Project Site, and all other rights on and to the Project Site. Any activities of the Landlord and/or its lessees or assignees or any other party shall not adversely affect the Project Site or the Facility or interfere with the Tenant’s operations or rights under this Ground Lease in any way. Nothing herein is intended to preclude the Landlord from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation. The Tenant may freely remove any timber which is standing or lying on the Project Site as the Tenant deems necessary for the Tenant’s intended use of the Project Site. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights below the surface of the Project Site.

 

13


(b) To the extent the Landlord holds any rights to oil, gas, or other minerals (“Minerals”) in the Project Site, the Landlord waives any and all rights of the Landlord or its lessees or assignees to use the surface of the Project Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the term of this Ground Lease, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means consistent with the terms and conditions of this Section 8.3(b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Facility or interfere with the Tenant’s operations or rights under this Ground Lease in any way.

8.4 Crossing. The Landlord shall assist the Tenant in the Tenant’s efforts to develop, at the Tenant’s cost, any roads and/or crossings or other Improvements across the property and boundary lines of the Project Site to the adjacent land, including relocation of utilities, providing culverts for storm water drainage, and any other Improvements. The Tenant or others, excluding the Landlord, will pay the cost to relocate or modify the infrastructure for these roads and/or crossings and/or other Improvements.

8.5 Pipelines; Rights of Way. If at any time the Tenant notifies the Landlord that the Project requires an off-Project Site pipeline and/or pipeline servitude for the development of the Project at the Project Site, the Landlord shall grant (with respect to its own real (immovable) property), or use its best efforts to cause the applicable landowners and Governmental Authorities to grant, the pertinent approvals to achieve the pipeline and/or pipeline right of way.

9. Indemnification.

9.1 Tenant’s General Agreement to Indemnify. The Tenant releases the Landlord, its officers, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, witness fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Landlord Indemnitee arising out of (i) the use or occupancy of the Project Site by the Tenant, its officers, representatives, agents, and employees, (ii) the construction or operation of the Project by the Tenant, its officers, representatives, agents, and employees, (iii) any claim arising out of the use, occupancy, construction or operation of the Project Site by the Tenant, its officers, representatives, agents, and employees, and (iv) activities on or about the Project Site by the Tenant, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, operation, maintenance, or repair of the Facility, the Improvements, or the Project Site by the Tenant, its officers, representatives, agents, and employees; provided, however, that any such claim, liability, obligation, damage or penalty arising as a result of the negligence or willful misconduct of any Landlord Indemnitee shall be excluded from this indemnity. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9.2 and 9.4 and not this Section 9.1.

 

14


9.2 Tenant’s Environmental Indemnification. For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with all Environmental Laws applicable to the Tenant, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Project Site. The Tenant agrees to indemnify and hold harmless the Landlord Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorney, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth above in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Project Site or any violation of any Environmental Law with respect to the Project Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, and maintenance activities or facilities and not caused by the Landlord’s Activities or Landlord’s Improvements.

9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Project Site by the Landlord, its officers, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Project Site by the Landlord, its officers, representatives, agents, and employees, and (iii) activities on or about the Project Site by the Landlord, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation, damage or penalty arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope but not be limited to any and all claims or actions for wrongful death, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.4 and not this Section 9.3.

9.4 Landlord’s Environmental Indemnification.

(a) For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Project Site. The Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses

 

15


(including, without limitation, reasonable attorneys, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances, or (ii) any actual or alleged violation of Environmental Laws, in the case of each of subclauses (i) and (ii), where the presence, discharge or release of such Hazardous Substances or violation of Environmental Law arises or occurs (1) at, on or from the Project Site on or prior to the Ground Lease Commencement Date or (2) at, on or from the Project Site or any other site as a result of or relating to the Landlord’s Activities or facilities or Landlord’s Improvements, whether before, on or after the Ground Lease Commencement Date, or (iii) the Landlord’s breach of the covenant set forth above in this Section 9.4 or (iv) any environmental condition of contamination on the Project Site or any violation of any Environmental Law with respect to the Project Site to the extent occurring after the Ground Lease Commencement Date and caused by the Landlord’s Activities or facilities.

(b) If Hazardous Substances become present or are discharged onto the Project Site as a result of the Landlord’s Activities or otherwise exist at the Project Site on or prior to the Ground Lease Commencement Date, the Tenant shall so notify the Landlord in writing as soon as practicable after the Tenant’s discovery thereof, and the Landlord shall have a reasonable period of time to undertake, at its own expense, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority, except that such removal or remediation shall not unreasonably interfere with the construction, operation or maintenance of the Facility and/or interfere the Improvements by the Tenant. The Tenant shall have the right to undertake such removal and remediation activities in its discretion, and the Landlord shall reimburse the Tenant (or the Tenant may offset against rent) for its reasonable and necessary documented costs therefor within thirty (30) days after receipt of an invoice by the Landlord (including any costs associated with the work stoppage or interference with the ability of any Facility Contractor to perform its respective obligations under the Facility Contracts (including mobilization and de-mobilization costs, suspension costs, storage costs, rescheduling penalties, and all other direct and indirect costs incurred by the Tenant or any Facility Contractor (and its respective subcontractors) as a result of any delay caused by such removal and/or remediation activities)). The Party not controlling the remediation under this Section 9.4(b) shall have a reasonable right of participation in the removal or remediation activities, including the right to (i) receive copies of material reports, work plans and correspondence relating to the removal or remediation activities, (ii) the right to review and comment on draft reports and work plans (and all reasonable comments shall be accepted by the controlling Party), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.4(b) shall not supersede or diminish the provisions or the Landlord’s obligations under Section 9.4(a).

9.5 Survival of Indemnities. The foregoing indemnities shall survive the Initial Term, any Extended Term, and any Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

 

16


10. Insurance.

10.1 Tenant Commercial General Liability. The Tenant shall carry or cause to be carried commercial general liability insurance with respect to the Project Site and the uses and activities of the Tenant thereon with minimum limits of [***]. The Tenant may elect to be self-insured in amounts greater than those minimum limits. In the event the Tenant procures commercial general liability insurance, the Landlord will be named as an additional insured.

10.2 Landlord Commercial General Liability. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Project Site and/or any activities of the Landlord with respect to the Project Site in its reasonable business discretion. The Landlord may elect to be self-insured.

11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. The Landlord shall not create or permit to be created or to remain in connection with the Project Site, the Facility or the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Project Site or upon the Landlord’s interest in the Project Site or upon the Tenant’s interest in its leasehold of the Project Site, in accordance with Section 11.2.

11.2 Discharge of Liens. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Project Site or any part thereof in connection with the Facility, the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Project Site or any part thereof in connection with the Facility, the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such Lien by deposit or by bonding proceedings. Any amount so paid by the non-responsible Party and all costs and expenses incurred by the non-responsible Party in connection therewith, including reasonable attorneys’ fees together with interest thereon at one percent (1%) per annum above the Wall Street Journal Prime Rate of interest published from time to time in the Wall Street Journal, from the respective dates of the non-responsible Party’s making of the payment or

 

17


incurring of the cost and expense, shall constitute either additional rent payable by the Tenant under this Ground Lease or an offset against Rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Project Site, including without limitation, any liabilities, obligations and/or debts owed to laborers, vendors, brokers, materialmen, and other service providers, and then offset against the Rent any such amount(s) paid by the Tenant.

12. Entry on Premises by Landlord, Etc.

The Landlord and its representatives shall have no right to enter the Project Site, except as specifically authorized from time to time in advance in writing by the Tenant after written notice to the Tenant of such request by the Landlord; and such authorization shall be in the Tenant’s sole discretion, and if/when granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of the Tenant. Such entry on the Project Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions such that access to certain sections of the Project Site will be restricted.

13. Destruction by Fire or Other Casualty.

If the Facility or any Improvements erected on the Project Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the willful misconduct of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Facility or the Improvements. In the event that the Tenant so decides not to restore or reconstruct the Facility or the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove any ruins or rubble remaining on the Project Site at the Tenant’s sole cost and expense.

14. Assignment; Subleasing; Right of First Refusal.

14.1 Restrictions on Landlord. The Landlord shall not assign this Ground Lease or sell the Project Site, in whole or in part, (including without limitation by transfer of control or otherwise) without the prior written consent of the Tenant or having complied with Section 14.3, as applicable. This Ground Lease shall inure to the benefit of and shall be binding upon the Landlord’s permitted assigns.

 

18


14.2 Restrictions on Tenant. Subject to the provisions of Section 23, the Tenant shall not assign this Ground Lease, in whole or in part, without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least thirty (30) days prior written notice of any proposed assignment, together with a copy of the proposed assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing, including to a Leasehold Lender, (ii) to a Leasehold Lender or any purchaser upon a foreclosure of a Leasehold Mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a Leasehold Mortgage, (iii) to any Affiliate or member of the Tenant, (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, or (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder. The Tenant shall not sublease all or any portion of the Project Site without the prior written consent of the Landlord, which consent shall not be unreasonably withheld, delayed or conditioned.

14.3 Right of First Refusal. During the Initial Term or any Extended Term of this Ground Lease, the Landlord may not transfer a portion of the Project Site and may only transfer the entire Project Site through a bona fide sale in exchange for a sum certain of money. If the Landlord, during the Initial Term or any Extended Term of this Ground Lease, makes a bona fide offer to sell or receives a bona fide offer from a third party to buy or acquire (individually and collectively a “Bona Fide Offer”) all or any portion of the Project Site separately or as a part of a larger parcel of which the Project Site is a part, the Landlord will promptly, within ten (10) Business Days of such making or receipt, give written notice to the Tenant of the terms of the Bona Fide Offer made or received, including the cash price attributable to the Project Site. If the sale is a tract of which the Project Site is a part, then the cash price attributable to the Project Site will be that part of the cash price multiplied times a fraction, the denominator of which is the total number of acres in the Project Site and the numerator of which is the total number of acres in the larger tract to be sold. The notice shall also state the other terms and conditions of the proposed sale and the Landlord’s willingness to sell for that cash price and on those terms. Upon receiving the notice, the Tenant may exercise the right, in the manner specified below, to purchase either the property described in the Bona Fide Offer or the Project Site (or part thereof) at the lower of: (i) the stated cash price in the Bona Fide Offer or (ii) Fair Market Value, which shall not include any value of this Ground Lease, the Facility, the Improvements and/or Landlord’s Improvements in the determination of the Fair Market Value, pursuant to the process described in Sections 14.3 through 14.6. This Section 14.3 does not apply to transfers pursuant to successions or donations executed in accordance with Louisiana law.

14.4 Exercise of Right of First Refusal. If the Tenant elects to purchase the property or Project Site described in the Bona Fide Offer under the provisions of Section 14.3, or if the Tenant elects to seek the Fair Market Value under the provisions of Section 14.3, the Tenant must notify the Landlord of such election, doing so in writing delivered to the Landlord within thirty (30) Business Days after the date of the Landlord’s written notice to the Tenant of the Bona Fide Offer. If the Tenant elects to refuse the Bona Fide Offer, the Tenant need take no action whatsoever; further, if the Tenant fails to deliver to the Landlord a notice of the Tenant’s election within the time required for such notice, the Tenant will be deemed to have refused the Bona Fide Offer. If the Tenant refuses, or is deemed to have refused, the Bona Fide Offer, the Landlord is free to sell the property pursuant to the Bona Fide Offer subject to this Ground Lease and any Leasehold Mortgage, any New Lease and any Non-Disturbance Agreement, and continuation of the leasehold interest created by this Ground Lease and any New Lease.

 

19


14.5 Fair Market Valuation. If the Tenant elects to seek the Fair Market Value under the provisions of Section 14.3, then the Tenant shall notify the Landlord of the Tenant’s proposed Fair Market Value for the property or the Project Site, as the case may be. Thereafter, for a period of thirty (30) days following such notice the Parties shall in good faith attempt to agree upon the Fair Market Value. If the Parties do not agree upon the Fair Market Value within such thirty (30) days, each of the Parties shall within the next thirty (30) days appoint a qualified appraiser to appraise the Fair Market Value (the “First Appraiser” and the “Second Appraiser”) by notice to the other Party. If the Second Appraiser is not timely designated, the determination of the Fair Market Value shall be made solely by the First Appraiser. The First Appraiser, or each of the First Appraiser and the Second Appraiser if the Second Appraiser is timely designated, shall submit its determination of the Fair Market Value to the Parties within thirty (30) days of the date of its selection (or the selection of the Second Appraiser, as applicable). If there are two (2) appraisers and their respective determinations of the Fair Market Value vary by less than ten percent (10%) of the higher determination, the Fair Market Value shall be the average of the two determinations. If such determinations vary by ten percent (10%) or more of the higher determination, the two appraisers shall promptly designate a third appraiser (the “Third Appraiser”). Neither the Tenant nor the Landlord shall provide, and the First Appraiser and Second Appraiser shall be instructed not to provide, any information to the Third Appraiser as to the determinations of the First Appraiser and the Second Appraiser or otherwise influence such Third Appraiser’s determination in any way. The Third Appraiser shall submit its determination of the Fair Market Value to the Parties within thirty (30) days of the date of its selection. The Fair Market Value shall be equal to the average of the two closest of the three determinations. The determination of the Fair Market in accordance with the foregoing procedure shall be final and binding on the Parties. If any appraiser is only able to provide a range in which Fair Market Value would exist, the average of the highest and lowest value in such range shall be deemed to be such appraiser’s determination of the Fair Market Value. Each appraiser selected pursuant to the provisions of this Section 14.5 shall be a qualified Person with prior experience in appraising industrial lands in south Louisiana and that is not an interested Person with respect to either Party or such Party’s Affiliates. If the Tenant has invoked this process and when the Fair Market Value has been determined, then the Tenant must notify the Landlord in writing within thirty (30) days that the Tenant elects to purchase the property or Project Site at the lower of either the Fair Market Value determined or the Bona Fide Offer; and if the Tenant fails to notify the Landlord within this thirty (30) day period, then the Landlord is free to sell the property or Project Site pursuant to the Bona Fide Offer subject to this Ground Lease and any Leasehold Mortgage, any New Lease and any Non-Disturbance Agreement, and continuation of the leasehold interest created by this Ground Lease.

14.6 Continuation of Right. If for any reason the Project Site is not sold by the Landlord following a Bona Fide Offer from a third party, the right of first refusal granted and described in the preceding Sections 14.1 through 14.5 shall continue in full force and effect, on the same terms and conditions.

 

20


15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of fifteen (15) days after written notice thereof from the Landlord to the Tenant.

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15.1(a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Project Site or discharge from the Project Site shall not constitute an Event of Default.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages; Termination. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default, the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the Tenant shall be liable for such reasonable damages unless such Event of Default is reasonably remedied in a timely manner and all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default, together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and payable, and all costs and expenses reasonably incurred by or on behalf of the Landlord as a result of the Event of Default, including reasonable attorneys’ fees, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective and is not valid if the Landlord does not give prior written notice to the Tenant pursuant to Section 15.1.

(b) Landlord’s Right to Cure Tenant’s Event of Default. Upon the occurrence of an Event of Default of the Tenant which is not cured or having commenced curing by the Tenant within sixty (60) days as provided in Section 15.2(b), then, subject to the prior written consent of any Leasehold Lender under Section 23, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others to cure the Event of Default. The Tenant shall be

 

21


responsible for all costs, including attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord.

15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Project Site to the Landlord, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Project Site and may have, hold, and enjoy the Project Site; and (ii) all obligations of the Tenant hereunder for additional rent or any portion thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. In the event of any termination, the Landlord shall be under a duty to seek a successor tenant. If the Landlord obtains a successor tenant during what would have been the remainder of the term of this Ground Lease, the Tenant shall receive a credit for rentals collected from said successor tenant for the remaining term of this Ground Lease. If no successor tenant is obtained, the Tenant shall be liable for Rent obligations otherwise provided for in this Ground Lease.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Project Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

16. Events of Default of the Landlord.

16.1 Landlord’s Event of Default; Right to Cure. Any failure of the Landlord to perform and/or to comply with any of its obligations, covenants, agreements, terms, or conditions contained in this Ground Lease shall constitute a “Landlord’s Event of Default” hereunder. The Landlord shall have sixty (60) days after notice by the Tenant to the Landlord of Landlord’s Event of Default to fully cure Landlord’s Event of Default.

16.2 Tenant’s Remedies; Cure. In the event of a Landlord’s Event of Default which is not fully cured under Section 16.1, in addition to all other remedies available to the Tenant, the Tenant may cancel this Ground Lease by written notice to the Landlord. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof, and shall be immediately payable to the Tenant. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default which is not fully cured under Section 16.1.

 

22


16.3 Tenant’s Right to Cure Landlord’s Event of Default. Upon the occurrence of a Landlord’s Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord’s Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others, purchasing the required goods or services and procuring necessary insurance. The Landlord shall be responsible for all costs including attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

17. Mutual Obligations.

17.1 Late Charges; Interest. If any Rent or other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of ten (10) days after receipt of written notice, such sum shall bear a late charge equal to one percent (1.0%) of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise (excluding, however, specific performance against the Tenant) and the exercise or beginning of the exercise by the Parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

 

23


18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by United States registered or certified mail, return receipt and signature requested, postage prepaid, to the Parties at the following numbers and addresses:

 

  To the Tenant:

Venture Global Calcasieu Pass, LLC

 

c/o Venture Global LNG, Inc.

 

1001 19th Street North

 

Suite 1500

 

Arlington, VA 22209

 

Attention: General Counsel

 

Telephone: [***]

 

Email: [***]

 

  With a copy to:

[***]

 

Norman Business Law Center

 

145 East Street

 

Lake Charles, LA 70601

 

Telephone: [***]

 

Email: [***]

 

  To the Landlord:

Henry Venture, LLC

 

2837 West Sale Road

 

Lake Charles, LA 70605

 

Attention: [***]

 

Telephone: [***]

 

Email: [***]

 

  With a copy to:

Stockwell, Sievert, Viccellio, Clements & Shaddock, LLP

 

P.O. Box 2900

 

Lake Charles, LA 70602-2900

 

Telephone: [***]

 

Email: [***]

or to such other numbers or addresses as either above designated recipients may from time to time designate by written notice to the other designated recipient hereto at least fifteen (15) days in advance of an effective date stated therein.

18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mail, return receipt and signature requested, postage prepaid.

 

24


19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable possession of the Project Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Project Site during the Initial Term, any Extended Term and any Removal Period of this Ground Lease without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord. This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow compatible use of the remainder of their property adjacent to the Project Site and will not create or allow the creation of a visual, olfactory or auditory nuisance on said remainder of their property.

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that: (i) it is the sole owner of good title to all of the Project Site; (ii) the Project Site is subject to no Liens, privileges, encumbrances, defects in title, servitudes, easements, restrictions, dedications, leases, mineral leases, reservations or other exceptions to title; (iii) during the term hereof it shall not encumber the Project Site; (iv) it is authorized to make this Ground Lease for the term hereof; (v) the provisions of this Ground Lease do not and will not conflict with or violate any of the provisions of existing agreements between the Landlord and any third party; and (vi) the Landlord will deliver the Project Site free of all tenants and occupants and claims thereto. The Landlord has furnished to the Tenant’s counsel a complete and up-to-date abstract of title at the Landlord’s sole expense, prior to the execution of this Ground Lease.

20. Eminent Domain.

20.1 Complete Condemnation. If, during the term hereof, the whole of the Project Site shall be taken under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking) by any public or private authority, then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided that the Tenant shall share in the condemnation award as provided herein. The Tenant may continue to occupy the Project Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Project Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Project Site from and after the date of such taking.

20.2 Partial Condemnation. If, during the term hereof, any public or private authority shall, under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking), makes a taking resulting in the reduction of the surface area of the Project Site by fifteen percent (15%) or more, or of fifteen percent (15%) or more of the value of the Facility, the Improvements or the Landlord’s Improvements, or resulting in material interference to the Tenant’s Project or the Tenant’s ability to use in a commercially reasonable manner the

 

25


remainder of the Project Site or Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of the exercise of its election within one-hundred twenty (120) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2, the term hereof shall cease and terminate as of the last day of the calendar month in which such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant, and the Tenant shall share in the condemnation award as provided herein.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the term hereof shall continue in full force and effect, and the Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete taking pursuant to Section 20.1, the Tenant will be entitled to receive the portion of the condemnation award (or settlement) attributable to (i) the value of the Facility and Improvements and Landlord’s Improvements, and fixtures and other property located on the Project Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Project Site so taken, plus (iii) other compensation or benefits paid as a consequence of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking (if any such compensation or benefits are paid by the applicable taking authority) and the Landlord shall be entitled to recover that portion of the condemnation award (or settlement) fairly attributable to the value of the land taken. In the event Tenant’s Property, the Improvements or the Facility are not taken, the Tenant shall not be entitled to any portion of the award, and in the event no Landlord’s property is taken, the Landlord shall not be entitled to any portion of the award. In the event of a partial taking of the Improvements, Tenant’s Property and/or Facility, the entire award or settlement shall be paid to the Tenant. In the event of a partial taking of the Project Site, the Tenant will be entitled to receive the portion of the award attributable to (i) the value of the portion of the Facility, Improvements and Tenant’s Property located in the portion of the Project Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Project Site so taken, plus (iii) damage to the remaining Facility, and the Tenant will promptly restore the remaining portion of the Facility to the extent of the award payable to the Tenant. Nothing contained herein shall prohibit the Tenant’s claiming relocation damages or damages for lost profits or loss of leasehold advantage against the taking authority in any appropriate proceeding.

21. Temporary Taking or Other Deprivation.

If, during the term hereof, (i) less than all of the Landlord’s title to all or any portion of the Project Site is taken for temporary use or occupancy, or (ii) any public or private authority takes any action not resulting in a taking of all or any portion of the Project Site but resulting in a right to compensation therefor, such as changing of the grade of any street upon which the Project Site abuts, then, except as otherwise provided in Section 20, the Tenant shall be entitled to make claim for, recover, and retain all awards, whether pursuant to judgment, agreement, or otherwise, recoverable in connection therewith.

 

26


22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure; provided that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section 23 shall govern and control.

23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Project Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage, or any agent or trustee therefor, that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant. The term “Leasehold Mortgage” shall mean, at any point in time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Project Site and this Ground Lease. It is acknowledged and agreed that, during the term of this Ground Lease, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the term of this Ground Lease, the Tenant shall provide the Landlord with written notice of the identity, contact information and address for each Leasehold Lender (or the agent authorized to act on behalf of the Leasehold Lender), such notice to be provided to the Landlord by the Tenant within no less than a calendar year within which the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

23.2 Right to Perform for Tenant; Right to Cure.

(a) In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and the Landlord shall accept such performance by Leasehold Lender with the same force and effect as if

 

27


furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing.

(b) If any default in the performance of an obligation of the Tenant under this Ground Lease is not susceptible to being cured by Leasehold Lender, the Landlord shall have no right to terminate this Ground Lease with respect to such default and such default shall be deemed waived for the benefit of Leasehold Lender only; provided that:

(i) Leasehold Lender shall have commenced to cure (i) any other non-payment default of the Tenant that is susceptible to being cured by Leasehold Lender and (ii) any default in the payment of any portion of Rent, in each case, within the time periods prescribed under Section 23.2(a);

(ii) Leasehold Lender (or its designee) shall have commenced to acquire the Tenant’s interest in this Ground Lease and the Project Site or to commence foreclosure or other appropriate proceedings under the Leasehold Mortgage within the time periods prescribed under Section 23.2(a);

(iii) if Leasehold Lender (or its designee) shall acquire the Tenant’s interest in this Ground Lease and/or the Project Site, Leasehold Lender (or its designee) shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition; and

(iv) if any third party shall, by foreclosure or dation en paiement under the Leasehold Mortgage or by assignment or other transfer from Leasehold Lender, acquire the Tenant’s interest in and to the Project Site under this Ground Lease, such third party shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by a third party with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition.

However, if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then notwithstanding any provision in this Section 23 to the contrary, the Landlord may exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

 

28


23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’s prior written consent, and any such action taken without Leasehold Lender’s consent shall not be binding on the Tenant or Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.4 Delivery of Notices. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including, without limitation, any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been delivered to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in writing to the Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Project Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’s interests in the Project Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including, without limitation, the acquisition of the Tenant’s interest in this Ground Lease and the Project Site created thereby in a transaction described in this Section 23 or the taking of possession of the Project Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender; provided that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Project Site.

 

29


23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2, the purchaser at any sale of this Ground Lease and the interests in and to the Project Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including, without limitation, power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Project Site thereby created under any instrument of assignment or transfer in lieu of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Project Site thereby created.

23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, substantially all, or any part of the Project Site or the Tenant’s Facility. Rent shall continue to be due and payable as set forth in this Ground Lease.

23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent domain proceeding of all, substantially all, or any part of the Project Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Facility, the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Project Site created by this Ground Lease and the value of the leasehold improvements located on the Project Site, up to an amount equaling the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Facility and/or the Tenant’s interest in, under and to this Ground Lease; provided that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under applicable law to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this

 

30


Ground Lease. In the event of a taking of a portion of the Project Site, the Rent shall be reduced pro rata based upon the portion of the Project Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease.

23.9 New Direct Lease.

(a) If this Ground Lease is canceled or terminated for any reason (except in connection with a Bankruptcy Proceeding, for which the provisions of Section 23.10 are hereby agreed upon by the Landlord and the Tenant), and provided that Leasehold Lender has (i) commenced to cure and continues diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, and (ii) cured any payment default in respect of any portion of Rent, the Landlord hereby agrees that the Landlord shall, upon Leasehold Lender’s written election within one hundred twenty (120) days of such cancellation or termination, promptly enter in a new, direct lease with Leasehold Lender (or its nominee or any other party which Leasehold Lender may designate, including without limitation, the Tenant) with respect to the Project Site on the same terms and conditions as this Ground Lease (a “New Lease”), it being the intention of the parties to preserve this Ground Lease and the interests in and to the Project Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Said New Lease shall be superior to all rights, liens and interests intervening between the date of this Ground Lease and the granting of the New Lease and shall be free of any and all rights of the Tenant under this Ground Lease.

(b) The Tenant and the Landlord acknowledge and agree that Leasehold Lender shall have the right to encumber such direct New Lease and the estate created thereby with a deed of trust or a mortgage (as the case may be) on the same terms and with the same lien priority as the Leasehold Mortgage, it being the intention of the parties to preserve the priority of the Leasehold Mortgage, this Ground Lease and the interests in and to the Project Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. If this Ground Lease is rejected, cancelled or terminated for any reason and Leasehold Lender, its nominee or a designee of Leasehold Lender enters into a direct lease with the Landlord with respect to the Project Site, the Landlord hereby agrees that it will execute such documents as Leasehold Lender may require in order to ensure that the new direct lease provides for customary leasehold mortgagee protections, including without limitation, protections similar to those contained herein.

23.10 Bankruptcy. In the event of a proceeding under the United States Bankruptcy Code (Title 11 U.S.C.) as now or hereafter in effect (a “Bankruptcy Proceeding”):

(a) If this Ground Lease is rejected in connection with a Bankruptcy Proceeding by the Tenant or a trustee in bankruptcy (or other party to such proceeding) for the Tenant, such rejection shall be deemed an assignment by the Tenant to the Leasehold Lender of the Tenant’s Property and all of the Tenant’s interest under this Ground Lease, and this Ground Lease shall not terminate and the Leasehold Lender shall have all rights and obligations of the Tenant as if such Bankruptcy Proceeding had not occurred, unless Leasehold Lender shall reject such deemed assignment by notice in writing to the Landlord within thirty (30) days following rejection of this

 

31


Ground Lease by the Tenant or the Tenant’s trustee in bankruptcy. If any court of competent jurisdiction shall determine that this Ground Lease shall have been terminated notwithstanding the terms of the preceding sentence as a result of rejection by the Tenant or the trustee in connection with any such proceeding, the rights of Leasehold Lender to a New Lease from the Landlord pursuant to Section 23.9 hereof shall not be affected thereby.

(b) In the event of a Bankruptcy Proceeding against the Landlord:

(i) If the bankruptcy trustee, the Landlord (as debtor-in-possession) or any party to such Bankruptcy Proceeding seeks to reject this Ground Lease pursuant to United States Bankruptcy Code §365(h)(l), the Tenant shall not have the right to treat this Ground Lease as terminated except with the prior written consent of Leasehold Lender and the right to treat this Ground Lease as terminated in such event shall be deemed assigned to Leasehold Lender, whether or not specifically set forth in the Leasehold Mortgage, so that the concurrence in writing of the Tenant and the Leasehold Lender shall be required as a condition to treating this Ground Lease as terminated in connection with such Bankruptcy Proceeding.

(ii) Unless this Ground Lease is treated as terminated in accordance with Section 23.10(b)(i), then this Ground Lease shall continue in effect upon all the terms and conditions set forth herein, including Rent, but excluding requirements that are not then applicable or pertinent to the remainder of the term of this Ground Lease. Thereafter, the Tenant or its successors and assigns shall be entitled to any offsets against Rent payable hereunder for any damages arising from such bankruptcy, to the extent the Tenant’s operation of business has been materially interfered with, and any such offset properly made shall not be deemed a default under this Ground Lease. The lien of the Leasehold Mortgage shall extend to the continuing possessory rights of the Tenant following such rejection with the same priority as it would have enjoyed had such rejection not taken place.

23.11 Estoppel Certificates; Non-Disturbance Agreements.

(a) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel”) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under the Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant thereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that each of this Ground Lease and the Non-Disturbance Agreement, true, correct copies of which shall be

 

32


attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, have not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Project Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Landlord’s power and authority to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Project Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Project Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, and any Non-Disturbance Agreement, there do not exist any other agreements concerning the Project Site or this Ground Lease, whether oral or written, to which Landlord is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Project Site, other than those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the Landlord Estoppel, the present lessor under this Ground Lease and owns good and indefeasible title to the Project Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Project Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Project Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Project Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (xix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

(b) Within fifteen (15) days following Leasehold Lender’s or the Landlord’s written request, the Tenant shall provide Leasehold Lender with an estoppel certificate (the “Tenant Estoppel”) which shall certify to such requesting Leasehold Lender (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Landlord of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Landlord of any other conditions required under this Ground Lease, (iii) as to any existing default of the Landlord under this Ground Lease, or alternatively that the Landlord is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Landlord hereunder, and as to any existing event or condition in existence as of the date of the Tenant Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Tenant to terminate, accelerate, or modify this Ground Lease or exercise any

 

33


other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Tenant, (v) that this Ground Lease, a true and correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Project Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Tenant’s power and authority to execute the Tenant Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Tenant asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Project Site, (x) as to any written notice received by the Tenant from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Project Site, (xi) that there are no fees, rents, royalties, or other sums, whether or not constituting rent, due and owing as of the date of the Tenant Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, there do not exist any other agreements concerning the Project Site or this Ground Lease, whether oral or written, to which the Tenant is a party, other than those set forth on a schedule to the Tenant Estoppel, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Project Site, other than those set forth on a schedule to the Tenant Estoppel, (xiv) that the Tenant is, as of the date of the Tenant Estoppel, the present lessee under this Ground Lease and holds a valid leasehold interest in the Project Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Tenant has not assigned, sublet, hypothecated, leased, or otherwise transferred it interests, or any portion thereof, in and to the Project Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Tenant’s interest in the Project Site, other than those set forth on a schedule to the Tenant Estoppel, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Tenant is a party or by which the Tenant is otherwise bound affecting the Tenant’s interest in and to the Project Site, (xvii) that the Tenant has not commenced any action or sent any notice to the Landlord for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Tenant is not, as of the date of the Tenant Estoppel, entitled to terminate, cancel, modify, or surrender this Ground Lease, and (xviii) as to such other matters related to this Ground Lease as such Leasehold Lender may reasonably determine from time to time.

(c) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall enter into a non-disturbance agreement with Leasehold Lender or its designee, in the form attached hereto as Exhibit 5 (a “Non-Disturbance Agreement”).

23.12 No Termination by Confusion. There shall be no termination by confusion of this Ground Lease or any interest in this Ground Lease or of the interests in and to the Project Site created thereby, by reason of the fact that this Ground Lease or such interest therein may be directly or indirectly owned by any person who shall hold any ownership interest in the Project Site, nor shall there be such a termination by confusion by reason of the fact that all or any part of the interests in and to the Project Site created by this Ground Lease may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any ownership interest in the Project Site or any ownership interest of the Landlord under this Ground Lease.

 

34


23.13 Landlord’s Recognition of Tenant. The Landlord hereby recognizes the Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that the Tenant acquired its interest in this Ground Lease and in and to the Project Site in accordance with the terms of this Ground Lease.

23.14 Agreement to Amend. The Landlord recognizes the importance of the Tenant’s ability to obtain Leasehold Mortgages, and that the provisions of this Ground Lease may be subject to the approval of a Leasehold Lender. If any Leasehold Lender should require, as a condition to such financing, any reasonable modifications of this Ground Lease, whether for purposes of clarifying the provisions of this Ground Lease or to include provisions then customary for leasehold financing transactions, the Landlord agrees to execute the appropriate amendments to this Ground Lease; provided, however, that no such modification shall, to the detriment of the Landlord, impair any of the Landlord’s rights, as reasonably determined by the Landlord or increase any of the Landlord’s obligations, as reasonably determined by the Landlord, under this Ground Lease.

23.15 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

23.16 Subordination of Landlord’s Lien. The Landlord hereby subordinates any lien or privilege it may have on any movables found from time to time in or upon the Project Site, including without limitation, the Landlord’s privileges pursuant to La. Civil Code articles 2707, et seq., to any Leasehold Lender’s rights under this Section 23 and the lien of any Leasehold Mortgage.

24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

24.2 Successors. The covenants, agreements, terms, provisions, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties hereto.

24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

 

35


24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

24.6 No Oral Change or Termination. This Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties hereto with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, including the Original Ground Lease, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

24.9 Litigation. In case of any litigation between the Parties hereto regarding the subject matter hereof, the losing Party shall pay all reasonable costs and expenses (including reasonable attorneys’ fees) of the prevailing Party. The venue of any litigation shall be solely in Calcasieu Parish.

24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

 

36


24.11 Authority. Each of the Landlord and the Tenant represents and warrants that it has the authority to enter into this Ground Lease, that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date, (a) the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 3, evidencing its authority to execute and perform under this Ground Lease and (b) the Landlord shall deliver to the Tenant a resolution in the form attached hereto as Exhibit 4, evidencing its authority to execute and perform under this Ground Lease.

24.12 Brokers and/or Real Estate Agents. Except with respect to the participation of Reinauer Real Estate Corporation in assisting the Tenant and the Landlord to structure this transaction, each of the Landlord and the Tenant represents, acknowledges and agrees that it is not represented by any other real estate broker/agent and that, except as provided below, it is not responsible for payment of any other commissions to any real estate brokers/agents in connection with this Ground Lease. The Tenant has previously paid to Reinauer Real Estate Corporation commissions under the relevant Option Agreement(s). The Landlord agrees that it is responsible for payment of any and all commissions owed to Reinauer Real Estate Corporation pursuant to this Ground Lease, which shall be the sum of (a) four percent (4%) of the Initial Parcels Rent plus (b) two percent (2%) of the Subsequent Parcel Rent, for the Term and any Extended Term of this Ground Lease, commencing on the Ground Lease Commencement Date.

24.13 Legal Relationships; Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. There is no third party beneficiary of this Ground Lease, except as provided in Section 23.15 and any rights of a Leasehold Lender as provided herein. This Ground Lease is the product of the Parties joint negotiation and equal drafting thereof. The language of this Ground Lease shall be construed as a whole according to its fair meaning and not construed strictly for or against any of the Parties pursuant to any statue, case law or rule of interpretation or construction to the contrary.

24.14 Settlement Funds. The Landlord and the Tenant acknowledge that the Landlord has a claim for property damages submitted to the Claims Administrator’s office of the BP Oil Spill/Deepwater Horizon Class Action Settlement, which allows for recovery of damages to coastal property. The recovery on any damage award from the Class Action Settlement is reserved solely for the benefit of the Landlord. The Landlord and the Tenant further agree that any similar claims, which may exist for damage to the Project Site, exclusive of any improvements of the Tenant, shall also be reserved to the sole benefit of the Landlord. Similar claims which may exist for damage to Tenant improvements and/or operations shall be reserved to the sole benefit of the Tenant.

24.15 Limited Recourse. The Landlord agrees that the sole recourse of the Landlord for any damages or liabilities due by the Tenant hereunder shall be limited to the assets of the Tenant, without recourse individually or collectively to the members or the Affiliates of the Tenant, the Financing Parties or their respective directors, officers, agents, members, shareholders, managers, partners, employees or representatives.

 

37


24.16. Further Assurances. In connection with this Agreement and the transactions contemplated hereby, each Party shall execute and deliver any additional documents and instruments and perform any additional acts that may be necessary or appropriate to effectuate and perform the provisions of this Agreement and those transactions, including in connection with the requests of any Financing Parties or Leasehold Lender.

24.17 No Waiver or Surrender. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Project Site and no agreement to accept a surrender of the Project Site shall be valid unless it is in writing and signed by the Landlord.

24.18 Memorandum of Lease. The Parties hereto agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’s interest hereunder; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease.

[Remainder of page left intentionally blank; signatures on following pages]

 

38


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

    LANDLORD:
    HENRY VENTURE, LLC

/s/ Beth Hinten

     
WITNESS Beth Hinten     By:  

/s/ Ell Ray Henry

    Name: Ell Ray Henry
    Title: Manager

/s/ Carol Mack

     
WITNESS Carol Mack      

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Calcasieu and State of Louisiana, personally came and appeared Ell Ray Henry, who, after being sworn by me, did execute this agreement on the 20th day of June, 2019 at Lake Charles, State of Louisiana.

 

  

/s/ Alan McCall

  
   NOTARY PUBLIC   

 

    TENANT:
    VENTURE GLOBAL CALCASIEU PASS, LLC

/s/ John Thomson

     
WITNESS John Thomson     By:  

/s/ Keith Larson

    Name: Keith Larson
    Title: Secretary

/s/ Ben Davidson

     
WITNESS Ben Davidson      

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 21st day of June, 2019 at Arlington, State of Virginia.

 

  

/s/ Anette B. Thrasher

  
   NOTARY PUBLIC   

 

1


LIST OF EXHIBITS

 

Exhibit 1-A    Legal Description of Project Site
Exhibit 1-B    Project Site Survey Maps
Exhibit 2    Project and Facility Description
Exhibit 3    Tenant’s Corporate Resolution
Exhibit 4    Landlord’s Corporate Resolution
Exhibit 5    Form of Non-Disturbance Agreement

 

1


EXHIBIT 1-A

LEGAL DESCRIPTION OF THE PROJECT SITE

PARCEL “A”

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND A HALF INCH DIAMETER IRON PIPE; THENCE S.00°36’56”W., A DISTANCE OF 4,956.53 FEET TO A POINT ALONG THE EAST LINE OF SECTION 36, TOWNSHIP 15 SOUTH, RANGE 10 WEST; THENCE S.00°35’10”W., A DISTANCE OF 1,619.34 FEET ALONG THE EAST LINE OF SECTION 37, TOWNSHIP 15 SOUTH, RANGE 10 WEST TO A POINT BEING MARKED BY A FOUND 4” TRANSITE PIPE; SAID POINT BEING THE POINT OF BEGINNING; THENCE S.00°34’10”W., A DISTANCE OF 1,158.58 FEET ALONG THE EAST LINE OF SECTION 37, TOWNSHIP 15 SOUTH, RANGE 10 WEST TO A POINT; THENCE S.71°00’02”W., A DISTANCE OF 69.44 FEET TO THE NORTHEAST CORNER OF THAT CERTAIN 93 ACRE PARCEL AS PER BOUNDARY AGREEMENT BETWEEN THE STATE OF LOUISIANA AND JOHN HENRY LEBLEU ET AL., RECORDED ON 10TH OF DECEMBER 1986 AND BEARING FILE NUMBER 202472 IN THE CONVEYANCE RECORDS OF CAMERON PARISH, LOUISIANA; THENCE S.01°00’00”W., A DISTANCE OF 940.66 FEET ALONG THE EAST LINE OF SAID BOUNDARY AGREEMENT; THENCE N.75°07’54”W., A DISTANCE OF 109.03 FEET ALONG THE SOUTH LINE OF SAID BOUNDARY AGREEMENT; THENCE N.85°59’22”W., A DISTANCE OF 190.44 FEET ALONG THE SOUTH LINE OF SAID BOUNDARY AGREEMENT; THENCE S.80°39’48”W., A DISTANCE OF 97.89 FEET ALONG THE SOUTH LINE OF SAID BOUNDARY AGREEMENT; THENCE S.68°21’17”W., A DISTANCE OF 274.12 FEET ALONG THE SOUTH LINE OF SAID BOUNDARY AGREEMENT; THENCE S.71°50’35”W., A DISTANCE OF 301.52 FEET ALONG THE SOUTH LINE OF SAID BOUNDARY AGREEMENT; THENCE S.63°25’56”W., A DISTANCE OF 134.62 FEET ALONG THE SOUTH LINE OF SAID BOUNDARY AGREEMENT; THENCE S.72°39’29”W., A DISTANCE OF 1,634.38 FEET ALONG THE SOUTH LINE OF SAID BOUNDARY AGREEMENT; THENCE N.73°39’39”W., A DISTANCE OF 752.41 FEET ALONG THE SOUTH LINE OF SAID BOUNDARY AGREEMENT; THENCE N.73°39’39”W., A DISTANCE OF 26.47 FEET ALONG THE SOUTH LINE OF SAID BOUNDARY AGREEMENT; THENCE N.07°12’01”W., A DISTANCE OF 619.77 FEET ALONG THE WEST LINE OF SAID BOUNDARY AGREEMENT; THENCE N.51°02’01”E., A DISTANCE OF 280.55 FEET ALONG THE WEST LINE OF SAID BOUNDARY AGREEMENT; THENCE N.20°41’46”E., A DISTANCE OF 184.20 FEET ALONG THE WEST LINE OF SAID BOUNDARY AGREEMENT; THENCE N.05°30’01”W., A DISTANCE OF 37.91 FEET ALONG SAID BANK LINE; THENCE N.05°30’01”W, A DISTANCE OF 412.09 FEET ALONG THE WEST LINE OF SAID BOUNDARY AGREEMENT; THENCE S.89°59’58”E., A DISTANCE OF 210.94 FEET ALONG THE NORTH LINE OF SAID BOUNDARY AGREEMENT TO A POINT ALONG THE LEFT DESCENDING BANK LINE OF THE CALCASIEU RIVER SHIP CHANNEL; THENCE N.11°18’36”W., A DISTANCE OF 16.68 FEET ALONG SAID BANK LINE; THENCE N.23°11’55”W., A DISTANCE OF 21.45 FEET ALONG SAID BANK LINE; THENCE N.34°22’49”W., A DISTANCE OF 16.21 FEET ALONG SAID BANK LINE; THENCE N.20°25’13”W., A DISTANCE OF 20.19 FEET ALONG SAID

 

2


BANK LINE; THENCE N.12°43’28”W., A DISTANCE OF 22.38 FEET ALONG SAID BANK LINE; THENCE N.42°57’17”E., A DISTANCE OF 27.91 FEET ALONG SAID BANK LINE; THENCE N.25°20’46”E., A DISTANCE OF 14.81 FEET ALONG SAID BANK LINE; THENCE N.26°33’54”W., A DISTANCE OF 9.45 FEET ALONG SAID BANK LINE; THENCE N.57°43’28”W., A DISTANCE OF 15.83 FEET ALONG SAID BANK LINE; THENCE N.63°26’06”W., A DISTANCE OF 15.75 FEET ALONG SAID BANK LINE; THENCE N.12°43’28”W., A DISTANCE OF 22.38 FEET ALONG SAID BANK LINE; THENCE N.11°02’27”W., A DISTANCE OF 29.42 FEET ALONG SAID BANK LINE; THENCE N.15°22’35”E., A DISTANCE OF 29.22 FEET ALONG SAID BANK LINE; THENCE N.10°37’11”E., A DISTANCE OF 11.46 FEET ALONG SAID BANK LINE; THENCE N.32°37’09”E., A DISTANCE OF 20.90 FEET ALONG SAID BANK LINE; THENCE N.22°55’56”E., A DISTANCE OF 19.88 FEET ALONG SAID BANK LINE; THENCE N.11°46’06”E., A DISTANCE OF 17.27 FEET ALONG SAID BANK LINE; THENCE N.23°57’45”W., A DISTANCE OF 13.87 FEET ALONG SAID BANK LINE; THENCE N.12°31’44”W., A DISTANCE OF 19.48 FEET ALONG SAID BANK LINE; THENCE N.16°19’43”E., A DISTANCE OF 43.02 FEET ALONG SAID BANK LINE; THENCE N.05°18’52”E., A DISTANCE OF 19.01 FEET ALONG SAID BANK LINE; THENCE N.12°25’33”E., A DISTANCE OF 26.59 FEET ALONG SAID BANK LINE; THENCE N.22°59’19”E., A DISTANCE OF 15.78 FEET ALONG SAID BANK LINE; THENCE N.18°53’10”W., A DISTANCE OF 17.68 FEET ALONG SAID BANK LINE; THENCE N.01°41’05”W., A DISTANCE OF 14.97 FEET ALONG SAID BANK LINE; THENCE N.06°06’56”E., A DISTANCE OF 12.40 FEET ALONG SAID BANK LINE; THENCE N.18°26’06”E., A DISTANCE OF 9.74 FEET ALONG SAID BANK LINE; THENCE N.12°05’41”E., A DISTANCE OF 18.91 FEET ALONG SAID BANK LINE; THENCE N.05°06’08”W., A DISTANCE OF 24.75 FEET ALONG SAID BANK LINE; THENCE N.23°53’11”W., A DISTANCE OF 33.70 FEET ALONG SAID BANK LINE; THENCE N.12°52’43”W., A DISTANCE OF 23.78 FEET ALONG SAID BANK LINE; THENCE N.21°02’15”E., A DISTANCE OF 12.26 FEET ALONG SAID BANK LINE; THENCE N.01°25’56”E., A DISTANCE OF 17.61 FEET ALONG SAID BANK LINE; THENCE N.36°52’12”W., A DISTANCE OF 6.60 FEET ALONG SAID BANK LINE; THENCE N.50°00’47”W., A DISTANCE OF 17.81 FEET ALONG SAID BANK LINE; THENCE N.05°42’38”W., A DISTANCE OF 13.27 FEET ALONG SAID BANK LINE; THENCE N.07°18’21”E., A DISTANCE OF 17.31 FEET ALONG SAID BANK LINE; THENCE N.29°03’17”E., A DISTANCE OF 18.13 FEET ALONG SAID BANK LINE; THENCE N.00°00’00”E., A DISTANCE OF 22.45 FEET ALONG SAID BANK LINE; THENCE N.01°35’28”E., A DISTANCE OF 31.70 FEET ALONG SAID BANK LINE; THENCE N.26°30’51”W., A DISTANCE OF 16.66 FEET ALONG SAID BANK LINE; THENCE N.02°07’16”W., A DISTANCE OF 14.87 FEET ALONG SAID BANK LINE; THENCE N.20°33’22”W., A DISTANCE OF 7.05 FEET ALONG SAID BANK LINE; THENCE N.05°56’49”E., A DISTANCE OF 13.28 FEET ALONG SAID BANK LINE; THENCE N.00°44’39”E., A DISTANCE OF 21.18 FEET ALONG SAID BANK LINE; THENCE N.30°37’45”W., A DISTANCE OF 10.27 FEET ALONG SAID BANK LINE; THENCE N.23°37’46”W., A DISTANCE OF 12.30 FEET ALONG SAID BANK LINE; THENCE N.05°42’38”W., A DISTANCE OF 14.16 FEET ALONG SAID BANK LINE; THENCE N.22°09’59”E., A DISTANCE OF 20.53 FEET ALONG SAID BANK LINE; THENCE N.14°25’15”E., A DISTANCE OF 25.45 FEET ALONG SAID BANK LINE; THENCE

 

3


N.00°36’17”E., A DISTANCE OF 80.08 FEET ALONG SAID BANK LINE; THENCE N.07°07’30”E., A DISTANCE OF 27.25 FEET ALONG SAID BANK LINE; THENCE N.20°51’16”E., A DISTANCE OF 25.32 FEET ALONG SAID BANK LINE; THENCE N.22°42’52”E., A DISTANCE OF 52.53 FEET ALONG SAID BANK LINE; THENCE N.17°49’08”E., A DISTANCE OF 66.28 FEET ALONG SAID BANK LINE; THENCE N.22°33’26”E., A DISTANCE OF 79.31 FEET ALONG SAID BANK LINE; THENCE N.27°33’27”E., A DISTANCE OF 26.18 FEET ALONG SAID BANK LINE; THENCE N.24°34’02”E., A DISTANCE OF 54.21 FEET ALONG SAID BANK LINE; THENCE N.05°07’02”E., A DISTANCE OF 47.37 FEET ALONG SAID BANK LINE; THENCE N.00°28’39”E., A DISTANCE OF 84.52 FEET ALONG SAID BANK LINE; THENCE N.03°04’06”E., A DISTANCE OF 78.00 FEET ALONG SAID BANK LINE; THENCE N.03°44’22”E., A DISTANCE OF 172.77 FEET ALONG SAID BANK LINE; THENCE N.12°31’44”E., A DISTANCE OF 20.78 FEET ALONG SAID BANK LINE; THENCE N.41°11’09”E., A DISTANCE OF 11.98 FEET ALONG SAID BANK LINE; THENCE N.27°33’10”E., A DISTANCE OF 29.23 FEET ALONG SAID BANK LINE; THENCE N.01°11’37”E., A DISTANCE OF 54.10 FEET ALONG SAID BANK LINE; THENCE N.01°19’56”E., A DISTANCE OF 48.47 FEET ALONG SAID BANK LINE; THENCE N.11°46’52”W., A DISTANCE OF 35.60 FEET ALONG SAID BANK LINE; THENCE N.82°24’19”E., A DISTANCE OF 21.31 FEET ALONG SAID BANK LINE; THENCE N.68°11’55”E., A DISTANCE OF 15.17 FEET ALONG SAID BANK LINE; THENCE N.59°51’31”E., A DISTANCE OF 25.25 FEET ALONG SAID BANK LINE; THENCE N.30°57’50”E., A DISTANCE OF 32.85 FEET ALONG SAID BANK LINE; THENCE N.40°36’05”E., A DISTANCE OF 45.45 FEET ALONG SAID BANK LINE; THENCE N.19°17’24”E., A DISTANCE OF 29.85 FEET ALONG SAID BANK LINE; THENCE N.09°07’49”E., A DISTANCE OF 39.95 FEET ALONG SAID BANK LINE; THENCE N.00°39’04”W., A DISTANCE OF 61.98 FEET ALONG SAID BANK LINE; THENCE N.08°58’26”E., A DISTANCE OF 39.05 FEET ALONG SAID BANK LINE; THENCE N.16°15’37”E., A DISTANCE OF 11.00 FEET ALONG SAID BANK LINE; THENCE N.59°02’10”E., A DISTANCE OF 15.40 FEET ALONG SAID BANK LINE; THENCE N.39°33’35”E., A DISTANCE OF 13.13 FEET ALONG SAID BANK LINE; THENCE N.19°39’14”E., A DISTANCE OF 13.09 FEET ALONG SAID BANK LINE; THENCE N.16°53’12”E., A DISTANCE OF 25.76 FEET ALONG SAID BANK LINE; THENCE N.19°58’59”E., A DISTANCE OF 15.46 FEET ALONG SAID BANK LINE; THENCE N.33°01’26”E., A DISTANCE OF 21.00 FEET ALONG SAID BANK LINE; THENCE N.04°09’35”E., A DISTANCE OF 24.27 FEET ALONG SAID BANK LINE; THENCE N.16°06’11”E., A DISTANCE OF 20.95 FEET ALONG SAID BANK LINE; THENCE N.35°12’21”E., A DISTANCE OF 26.79 FEET ALONG SAID BANK LINE; THENCE S.53°26’11”E., A DISTANCE OF 797.78 FEET; THENCE S.53°26’11”E., A DISTANCE OF 440.00 FEET ; THENCE S.53°26’11 ”E., A DISTANCE OF 482.84 FEET; THENCE S.89°24’41 ”E., A DISTANCE OF 1,366.83 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 8,870,434.13 SQUARE FEET OR 203.6371 ACRES, MORE OR LESS, IS SITUATED IN SECTION 37, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “A” ON THE HERE TO ATTACHED PLAT.

 

4


PARCEL “B”

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND A HALF INCH DIAMETER IRON PIPE; THENCE S.00°36’56”W., A DISTANCE OF 4,956.53 FEET TO A POINT ALONG THE EAST LINE OF SECTION 36, TOWNSHIP 15 SOUTH, RANGE 10 WEST; THENCE S.00°35’10”W., A DISTANCE OF 1,619.34 FEET ALONG THE EAST LINE OF SECTION 37, TOWNSHIP 15 SOUTH, RANGE 10 WEST TO A POINT BEING MARKED BY A FOUND 4” TRANSITE PIPE; THENCE N.89°24’41”W., A DISTANCE OF 1,321.14 FEET TO A POINT BEING MARKED BY A SET ONE AND A QUARTER INCH DIAMETER IRON PIPE; SAID POINT BEING THE POINT OF BEGINNING; THENCE N.89°24’41”W., A DISTANCE OF 45.69 FEET TO A POINT BEING MARKED BY A SET ONE AND A QUARTER INCH DIAMETER IRON PIPE; THENCE N.53°26’11”W., A DISTANCE OF 482.84 FEET TO A POINT BEING MARKED BY A FOUND ONE AND A HALF INCH DIAMETER IRON PIPE; THENCE N.53°26’11”W., A DISTANCE OF 440.00 FEET TO A POINT BEING MARKED BY A SET HALF INCH DIAMETER IRON PIPE; THENCE N.53°26’11”W, A DISTANCE OF 797.78 FEET TO A ALONG THE LEFT DESCENDING BANK LINE OF THE CALCASIEU RIVER SHIP CHANNEL; SAID POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON PIPE, OFFSET 24.95’ S53°26’11 ”E OF TRUE POSITION; THENCE N.26°08’40”E., A DISTANCE OF 36.71 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.07°21’23”E., A DISTANCE OF 20.28 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.34°26’48”W., A DISTANCE OF 7.06 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.17°14’53”E., A DISTANCE OF 37.22 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.15°22’46”E., A DISTANCE OF 22.37 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.16°55’06”E., A DISTANCE OF 13.44 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.70°11’55”E., A DISTANCE OF 8.73 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.32°44’46”E., A DISTANCE OF 25.84 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.32°11’37”E., A DISTANCE OF 31.17 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.17°44’06”W., A DISTANCE OF 3.62 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.28°16’55”E., A DISTANCE OF 6.79 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.27°47’25”W., A DISTANCE OF 5.04 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.81°17’51”E., A DISTANCE OF 3.89 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.00°47’49”W., A DISTANCE OF 18.83 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.60°47’50”E., A DISTANCE OF 9.65 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.47°13’06”E., A DISTANCE OF 17.52 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.18°14’14”E., A DISTANCE OF 17.59 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.34°58’46”E., A DISTANCE OF 8.57 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.01°08’01”W., A DISTANCE OF 25.22 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.36°53’09”W., A DISTANCE OF 5.07 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.03°16’43”E., A DISTANCE OF 3.76 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.32°15’50”E., A DISTANCE OF 3.22 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.07°37’37”W., A DISTANCE OF 34.71 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.10°46’10”E., A DISTANCE OF 12.83 FEET TO A POINT ALONG SAID BANK LINE; THENCE

 

5


N.02°23’05”E., A DISTANCE OF 8.46 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.26°53’40”E., A DISTANCE OF 22.72 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.20°48’06”E., A DISTANCE OF 18.65 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.00°00’00”E., A DISTANCE OF 22.91 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.06°18’14”W., A DISTANCE OF 22.10 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.27°32’56”E., A DISTANCE OF 8.99 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.03°25’01”E., A DISTANCE OF 12.47 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.19°12’16”E., A DISTANCE OF 13.77 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.01°34’33”E., A DISTANCE OF 16.00 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.21°40’58”W., A DISTANCE OF 40.45 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.35°05’11”W., A DISTANCE OF 16.72 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.17°53’57”W., A DISTANCE OF 41.80 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.18°44’33”W., A DISTANCE OF 33.94 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.23°05’31”W., A DISTANCE OF 30.16 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.40°51’35”W., A DISTANCE OF 26.52 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.29°19’49”W., A DISTANCE OF 20.27 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.21°59’50”W., A DISTANCE OF 24.93 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.11°31’05”E., A DISTANCE OF 26.56 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.00°56’15”W., A DISTANCE OF 25.49 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.06°15’37”E., A DISTANCE OF 46.38 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.09°31‘32”E., A DISTANCE OF 37.62 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.12°39’00”E., A DISTANCE OF 18.48 FEET TO A POINT ALONG SAID BANK LINE; THENCE N. 17°58’35”E., A DISTANCE OF 22.17 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.27°03’38”E., A DISTANCE OF 40.70 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.34°01’19”E., A DISTANCE OF 21.50 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.42°55’09”E., A DISTANCE OF 34.08 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.55°42’13”E., A DISTANCE OF 31.89 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.63°56’27”E., A DISTANCE OF 36.71 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.69°42’14”E., A DISTANCE OF 31.38 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.58°34’40”E., A DISTANCE OF 16.91 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.12°32’16”W., A DISTANCE OF 12.38 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.30°18’38”E., A DISTANCE OF 8.24 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.68°12’32”E., A DISTANCE OF 37.62 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.82°20’41”E., A DISTANCE OF 39.04 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.66°13’18”E., A DISTANCE OF 34.36 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.66°32’50”E., A DISTANCE OF 49.54 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.56°56’20”E., A DISTANCE OF 50.03 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.56°03’41”E., A DISTANCE OF 36.50 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.53°01’10”E., A DISTANCE OF 43.68 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.51°37’07”E., A DISTANCE OF 73.99 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.43°10’06”E., A DISTANCE OF 83.02 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.47°15’49”E., A DISTANCE OF 42.25 FEET TO A POINT ALONG SAID BANK LINE; THENCE

 

6


N.42°24’07”E., A DISTANCE OF 79.26 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.33°37’37”E., A DISTANCE OF 69.33 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.16°59’41”E., A DISTANCE OF 57.63 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.33°57’13”E., A DISTANCE OF 50.30 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.38°18’00”E., A DISTANCE OF 46.40 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.38°01’31”E., A DISTANCE OF 81.42 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.42°37’39”E., A DISTANCE OF 34.37 FEET TO A POINT ALONG SAID BANK LINE; THENCE N.37°30’21”E., A DISTANCE OF 74.43 FEET TO A POINT ALONG SAID BANK LINE; SAID POINT BEING MARKED BY A SET ONE AND A QUARTER INCH DIAMETER IRON PIPE, OFFSET 25.02’ S.83°47’07”E. OF TRUE POSITION; THENCE S.83°47’07”E., A DISTANCE OF 552.49 FEET TO A POINT BEING MARKED BY A SET ONE AND A QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°36’56”W., A DISTANCE OF 344.83 FEET TO A POINT BEING MARKED BY A SET ONE AND A QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°36’56”W., A DISTANCE OF 676.76 FEET BEING MARKED BY A SET ONE AND A QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°36’56”W., A DISTANCE OF 732.98 FEET BEING MARKED BY A SET ONE AND A QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°36’56”W., A DISTANCE OF 885.47 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 2,660,089.07 SQUARE FEET OR 61.0672 ACRES, MORE OR LESS, IS SITUATED IN SECTIONS 36 & 37, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “B” ON THE HERE TO ATTACHED PLAT.

 

7


EXHIBIT 1-B

SURVEY MAPS OF PROJECT SITE

[Omitted]


EXHIBIT 2

PROJECT AND FACILITY DESCRIPTION

[Omitted]


EXHIBIT 3

TENANT’S CORPORATE RESOLUTION

[Omitted]


EXHIBIT 4

LANDLORD’S CORPORATE RESOLUTION

[Omitted]


EXHIBIT 5

FORM OF NON-DISTURBANCE AGREEMENT

[Omitted]

Exhibit 10.54

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

 

  

STATE OF LOUISIANA

PARISH OF PLAQUEMINES

   Execution Version

GROUND LEASE AGREEMENT

This GROUND LEASE AGREEMENT (this “Ground Lease”) is executed and effective as of July 19, 2021 (the “Ground Lease Commencement Date”), by and between VENTURE GLOBAL PLAQUEMINES LNG, LLC, a Delaware limited liability company (the “Tenant”) and THE PLAQUEMINES PORT HARBOR AND TERMINAL DISTRICT, a political subdivision of the State of Louisiana (the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as a “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Plaquemines Parish, Louisiana, which comprises six hundred thirty-two and 998/1000 (632.998) acres;

WHEREAS, the Tenant wishes to lease land owned by the Landlord for the development, permitting, financing, construction, ownership, operation and/or maintenance of a natural gas liquefaction facility, which may be constructed in two phases, each having a nameplate capacity of ten (10) million metric tonnes per annum of LNG, as more fully described in Exhibit 2-A (the “Facility”) and the construction and installation of such other Improvements (as hereinafter defined) on the Site including other ancillary and/or related uses permitted by this Ground Lease;

WHEREAS, the granting of the leasehold interest created pursuant to this Ground Lease will add to the welfare and prosperity of the Persons residing within the geographic limits of numerous surrounding Parishes and throughout the State of Louisiana; and

WHEREAS, in accordance with the above, the Tenant has executed this Ground Lease and offers fair value to the Landlord as cause and consideration for this Ground Lease.

NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this Ground Lease, and the Parties herein covenant and agree as follows:

1. Definitions and Interpretation.

1.1 Definitions. As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

Adjustment Period” has the meaning set forth in Section 4.1(b).

Advance Rent Payment Aggregate Amount” has the meaning set forth in Section 4.1(c)(i).


Affiliate” means, in respect of any Person, any other Person controlled by, controlling or under common control with such first Person. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of fifty percent (50%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.

Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Site.

Bankruptcy Proceeding” has the meaning set forth in Section 23.10.

Bona Fide Offer” has the meaning set forth in Section 14.3.

Boundary Survey” means the boundary survey of the Site, dated October 15, 2020, by T. Baker Smith., attached as Exhibit 1-B.

Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in New York, New York are authorized or required by law to close.

Consumer Price Index” has the meaning set forth in Section 4.2.

Corps” has the meaning set forth in Section 8.3(a).

CPI Adjustment” has the meaning set forth in Section 4.1(b).

CPI Disagreement Notice” has the meaning set forth in Section 4.2.

CPI Notice” has the meaning set forth in Section 4.2.

CPI Percentage Increase” has the meaning set forth in Section 4.2.

DOE Reporting” has the meaning set forth in Section 4.1(e).

Environmental Assessment” has the meaning set forth in Section 9.6.

Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Laws or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Laws relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

 

2


Event of Default” has the meaning set forth in Section 15.1.

Extended Term” has the meaning set forth in Section 3.2(a).

Extension Payment Credit” means [***].

Facility” has the meaning set forth in the Recitals hereof.

Facility Contractor” means any Person (other than the Tenant or its Affiliate) that is party to a Facility Contract.

Facility Contracts” means, collectively, the contracts entered into by the Tenant in connection with the design, engineering, construction, equipment procurement, testing, commissioning, operation and maintenance of the Facility, the Site and/or the Improvements.

FERC Order” means the “Order Granting Authorizations Under Sections 3 and 7 of the Natural Gas Act” issued by the Federal Energy Regulatory Commission for the Plaquemines LNG Project, and the related Gator Express pipeline project, on September 30, 2019. 168 FERC ¶ 61,204 (2019).

FID” means that all conditions precedent set forth in the loan documents entered into by the Tenant or its Affiliates for the purposes of financing the Facility have been satisfied or waived and the Financing Parties party thereto have disbursed the initial loans thereunder.

Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Facility or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders.

Fitch” means Fitch, Inc. and its successors.

Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include, but not be limited to, the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, droughts, floods, washouts, explosions, breakage or accident or necessity of repairs to machinery or equipment or lines of pipe; (ii) weather related events affecting an entire geographic region; (iii) acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, terrorism, discovery of burial grounds or human remains or legally protected artifacts, insurrections or wars; and (iv) governmental actions such as necessity for compliance with any court order, law, statute, ordinance, regulation, or policy having the effect of law promulgated by a Governmental Authority having jurisdiction, or that restrict the Tenant’s ability to reasonably construct and/or operate the Facility or any delay in issuance or effectiveness of any Governmental Approval that has been properly applied for by the Tenant that is required to construct and/or operate the Facility. “Force Majeure” shall not include (i) the failure

 

3


or interruption of performance by the Tenant’s engineering, procurement and construction contractor or any subcontractors of such contractor, except to the extent caused by an event of Force Majeure; or (ii) the failure or interruption of performance by the Tenant’s suppliers, except to the extent caused by an event of Force Majeure.

Gator Express Servitude” has the meaning set forth in Section 8.6.

Governmental Approval” means any authorization, waiver, consent, approval, license, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority, including the FERC Order.

Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

Ground Lease” has the meaning set forth in the Preamble hereof.

Ground Lease Commencement Date” has the meaning set forth in the Preamble hereof.

Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

 

4


Hazardous Substances Law” means any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Laws or similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent it relates to the handling of and exposure to hazardous or toxic materials or similar substances.

Improvements” means any and all improvements made by the Tenant, in its sole discretion, to the Site, including improvements relating to the loading, unloading, handling, treatment, processing, producing, transporting, distributing, selling, metering and/or storing of (i) natural gas, natural gas liquids, and other natural gas products, derivatives and by-products and (ii) other petroleum and hydrocarbon liquids, gases, products, derivatives and by-products, including (A) the importation, regasification, production, exportation, liquefaction, refinement, enhancement, other treatment and transportation (including by ship, pipeline, truck or rail) of LNG, and LNG by-products and additives and (B) the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of any improvements, component parts and other constructions, fixtures, facilities, equipment and/or appurtenances (including natural gas pipelines, natural gas liquids extraction, processing and delivery facilities, acid gas removal units, natural gas liquefaction trains, LNG regasification facilities, and other treatment facilities, cryogenic pipelines, LNG storage tanks, petroleum and other hydrocarbon liquids storage facilities, nitrogen storage and processing facilities, power generation and transmission infrastructure, the Site Wall, marine, rail and trucking receipt, delivery and servicing facilities (including piers, marine terminals, bulkheads, wharfs, docks, inlets, wetslips, moonpools, moorings, jetties, and loading and unloading equipment), construction laydown areas and other utilities and facilities (including berms, open space, security fencing, control rooms, offices, warehouses, parking and yards), in each case, necessary, ancillary or desirable to the Tenant in connection with the foregoing. For the avoidance of doubt, none of the Improvements constitutes a Landlord’s Improvement.

Industrial Zone” means that certain area of land in Plaquemines Parish, Louisiana, comprised of the parcels of real (immovable) property, including the Site, as set forth in Exhibit 3. The Industrial Zone will form an area for promoting industrial developments such as the Facility.

Initial Term” has the meaning set forth in Section 3.1.

LA23” has the meaning set forth in Section 2.3.

Landlord” has the meaning set forth in the Preamble hereof.

Landlord Estoppel” has the meaning set forth in Section 23.11(a).

Landlord Event of Default” has the meaning set forth in Section 16.1.

 

5


Landlord Indemnitee” has the meaning set forth in Section 9.1.

Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, affiliates, invitees, agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Site and/or Landlord’s Improvements.

Landlord’s Improvements” has the meaning set forth in Section 6.1.

Lease Year” means a period of twelve (12) consecutive full calendar months. The first Lease Year shall begin on the Ground Lease Commencement Date. Each succeeding Lease Year shall commence upon the anniversary of the first day of the previous Lease Year.

Leasehold Lenders” has the meaning set forth in Section 23.1.

Leasehold Loan” has the meaning set forth in Section 23.1.

Leasehold Mortgage” has the meaning set forth in Section 23.1.

Letter of Credit” means an irrevocable standby letter of credit in a form reasonably similar to the attached Exhibit 11 and comporting with ICC Publication No. 590 (“ISP98”), naming the Landlord as the party entitled to demand payment and present draw requests thereunder that is issued by a commercial bank or trust company with a senior, unsecured debt rating of at least (i) BBB- from Standard & Poor’s Rating Group, (ii) Baa3 from Moody’s Investor Services, Inc. or (iii) BBB- from Fitch, Inc.

Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

LNG” means liquefied natural gas.

Minerals” has the meaning set forth in Section 8.3(b).

New Highway Route” has the meaning set forth in Section 2.3.

New Lease” has the meaning set forth in Section 23.9(a).

Non-Disturbance Agreement” has the meaning set forth in Section 23.11(c).

Option Agreement” means the Real Estate Lease Option Agreement between the Landlord and the Tenant, dated as of August 19, 2015, as amended by the First Amendment to Real Estate Lease Option Agreement, dated as of September 19, 2017, and the Second Amendment to Real Estate Lease Option Agreement, dated as of October 26, 2018.

 

6


Party” or “Parties” has the meaning set forth in the Preamble hereof.

Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

Property Taxes” means all real (immovable) and personal (moveable) property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

Removal Period” means the period of time that is required by the Tenant to remove any and all of the Tenant’s Property, including the Facility and/or Improvements, from the Site in accordance with Section 7.1.

Rent” has the meaning set forth in Section 4.1(a).

Rent Credit Amount” means an amount equal to the sum of the Advance Rent Payment Aggregate Amount and the Extension Payment Credit.

Site” means the real (immovable) property of approximately six hundred thirty-two (632) acres described in the legal description set forth in Exhibit 1-A, and illustrated by the Boundary Survey attached as Exhibit 1-B, upon which the Facility and other Improvements will be located and which real (immovable) property is owned by the Landlord.

Site Wall” means the 30 foot high steel wall that surrounds the Facility Site, as depicted on the plot plan attached as Exhibit 2-B.

Surface Waiver” has the meaning set forth in Section 8.3(b).

Tenant” has the meaning set forth in the Preamble hereof.

Tenant Estoppel” has the meaning set forth in Section 23.11(b).

Tenant Indemnitee” has the meaning set forth in Section 9.3.

Tenant Security” has the meaning set forth in Section 15.5.

Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Site by or on behalf of the Tenant, including the Facility and any Improvements.

Term” has the meaning set forth in Section 3.2(a).

 

7


Throughput Fee” has the meaning set forth in Section 4.1(f).

1.2 Interpretation. Unless the context otherwise requires:

(a) Words singular and plural in number will be deemed to include the other and pronouns having a masculine or feminine gender will be deemed to include the other;

(b) Any reference to this Ground Lease or any other contract or agreement in respect of the Site means such agreement and all schedules, exhibits and attachments thereto as may be amended, supplemented or otherwise modified and in effect from time to time, and shall include a reference to any document which amends, modifies or supplements it, or is entered into, made or given pursuant to or in accordance with its terms;

(c) The terms “hereof,” “herein,” “hereby,” “hereto” and similar words refer to this entire Agreement and not any particular Section, subsection or other subdivision of, or Exhibit, appendix or schedule to, this Ground Lease;

(d) The terms “include” and “including” shall be construed as being at all times followed by the words “without limitation” or “but not limited to” unless the context specifically indicates otherwise;

(e) References to “Article,” “Section” or “Exhibit” are to this Ground Lease unless specified otherwise;

(f) References to any law, statute, rule, regulation, notification or statutory provision (including Applicable Laws) shall be construed as a reference to the same as it may have been, or may from time to time be, amended, modified or re-enacted;

(g) References to any Person shall be construed as a reference to such Person’s successors, heirs and permitted assigns; and

(h) The word “or” will have the inclusive meaning represented by the phrase “and/or”.

2. Lease of Ground Lease Premises and Additional Obligations.

2.1 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of Rent and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does hereby lease to the Tenant and the Tenant hereby leases from the Landlord, the Site and Landlord’s Improvements.

2.2 Servitudes. In addition, the Landlord shall grant from time to time to the Tenant and others designated by the Tenant (including any Affiliate of the Tenant) any servitudes and rights of way reasonably requested by the Tenant on land owned or controlled by the Landlord for access and electricity, communications, gas, water, sewer and other utility lines, products and

 

8


materials from and to the Site over land and waterways sufficient to access adjacent lands owned by the Landlord and to permit the Tenant to accomplish its purposes in connection with the Facility and the Improvements; provided, that such easements, servitudes, or rights of way do not adversely affect or interfere with the development, construction, or operation of the Industrial Zone contemplated by the Landlord. The Tenant shall pay any out-of-pocket costs and expenses incurred by the Landlord in granting such easements, servitudes, and rights of way. If requested by the Landlord, the Landlord and the Tenant shall cooperate to relocate, to the extent possible, any such easements, servitudes or rights of way on the Site; provided that any such relocation does not adversely affect or interfere with the Facility, the Improvements, any expansion of the Facility or the Improvements contemplated by the Tenant, or the construction, ownership, operation or maintenance thereof.

2.3 Relocation of Highway 23. Louisiana State Highway 23 (“LA23”) traverses the entire length of the Industrial Zone and, in order to assist the Landlord in the development of the Industrial Zone consistent with appropriate public safety and traffic management considerations, the portion of LA23 that traverses the Industrial Zone could potentially be relocated to an alternate route running through the southwest portion of the Industrial Zone, generally depicted on Exhibit 8, attached hereto (the “New Highway Route”). Accordingly, the Landlord and the Tenant shall cooperate with and assist each other in the relocation of LA23 along with any utility or other servitudes currently located along LA23 to the New Highway Route or any other route within the Industrial Zone that the Landlord may reasonably request, including in preparing any engineering, environmental impact, constructability or other studies as may be required by the Louisiana Department of Transportation or other relevant governmental agencies, and applying for all necessary permits, licenses and approvals that may be required, in connection with such relocation of LA23 or the relevant servitudes, in each case so long as the foregoing would not require the Tenant to modify, relocate or otherwise alter any Improvements. Any effort by either Party in cooperating with, or assisting, the other Party in the relocation of LA23 pursuant to the preceding sentence will be limited to those efforts requiring no expenditure of out-of-pocket costs. From and after the Ground Lease Commencement Date, and regardless of whether LA23 is relocated, the Tenant shall assist and cooperate with the Landlord in its efforts to (a) modify encumbrances, servitudes, interests, use restrictions, and other title matters, and (b) obtain regulatory approvals, in each case, to locate portions of the Facility under and/or over LA23, so long as the same does not violate the FERC Order or require the Tenant to modify, relocate or otherwise alter any Improvements. Any effort by the Tenant in cooperating with, or assisting, the Landlord in the Landlord’s seeking of modifications to encumbrances, servitudes, interests, use restrictions, or other title matters and regulatory approval in locating portions of the Facility under and/or over LA23 pursuant to the preceding sentence will be limited to those efforts requiring no expenditure of out-of-pocket costs by the Tenant.

2.4 Cooperation with Rail. In recognition of Landlord’s development intentions within the Industrial Zone, Tenant agrees to reasonably cooperate with the introduction of rail, train and railway transportation facilities within the Industrial Zone, so long as they are located on areas of the Site that are not within the Site Wall. Tenant agrees that at all times: (i) during the Term, the Site Wall shall be located not less than 155 feet from the southern boundary line of the Site; (ii) during construction of the Site Wall, there will be at least (1) 55 feet of clearance immediately north of the southern boundary line (east of the Gator Express Servitude) and (2) 105 feet of

 

9


clearance immediately north of the southern boundary line (west of the Gator Express Servitude); and (iii) following the construction of the Site Wall, there will be at least 105 feet of clearance immediately north of the southern boundary line. Tenant shall not impede, prevent or delay the process of permitting such rail facilities within the Industrial Zone, so long as the same does not violate the FERC Order.

2. Term.

3.1 Initial Term. The initial term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on the thirtieth (30th) anniversary of the Ground Lease Commencement Date (the “Initial Term”).

3.2 Extensions.

(a) In consideration of and conditioned upon there being no uncured Event of Default on the part of the Tenant at the time an option is exercised, the Landlord hereby grants unto the Tenant the option to lease the Site for four (4) additional ten (10) year terms. If the extension option is exercised in accordance with Section 3.2(b), the first of said additional terms shall commence upon the expiration of the Initial Term and extend for a period of ten (10) years and each of said additional terms shall commence upon the expiration of the then current additional term and extend for a period of ten (10) years. Each such additional term is referred to herein as an “Extended Term” and the Initial Term as extended by any Extended Term(s) is referred to herein as the “Term”.

(b) The option to extend this Ground Lease of the Site as set forth in Section 3.2(a) must be exercised in each case, if at all, by written notice from the Tenant to the Landlord on or before the date that is three (3) months prior to the expiration of the Initial Term or the then-current Extended Term, as applicable. The failure of the Tenant to timely exercise the first Extended Term or any subsequent Extended Term shall automatically terminate the right of the Tenant to exercise its option to lease the Site in any subsequent Extended Term.

(c) All the terms and conditions of this Ground Lease shall be applicable to any Extended Term and the Rent payable by the Tenant for any Extended Term shall be in accordance with the provisions set forth in Article 4.

4. Rent.

4.1 Rent.

(a) Commencing upon the Ground Lease Commencement Date, the initial ground rent for the Site shall be [***] per annum, payable in equal installments of [***] per month (the “Rent”); provided, that if at any time during the term of this Ground Lease (i) the Landlord enters into a long-term lease for any real (immovable) property owned or leased by the Landlord that is located

 

10


within the Industrial Zone and has direct or indirect access to the Mississippi River with any person or entity other than a Tenant or its Affiliates and (ii) such lease contains economic terms (including rent) which are, in the aggregate, more favorable to such lessee than the economic terms of this Ground Lease, the Landlord and the Tenant shall promptly amend this Ground Lease in order that the Tenant shall obtain the benefit of such more favorable terms. Commencing on the fifth (5th) anniversary of the Ground Lease Commencement Date, the Rent shall be adjusted in accordance with Section 4.1(b). Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month; provided, however, that (x) the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first day of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; (y) the first payment of Rent due upon the commencement of any new Adjustment Period will be owed and paid one month after the commencement of that Adjustment Period, in order to permit the Tenant to calculate the CPI Adjustment as provided in Section 4.2; and (z) the last payment of Rent shall be in a prorated amount for the period of time between the immediately preceding first day of the month and the last day of the Term. The Landlord acknowledges and agrees that the Tenant shall be permitted to apply the Rent Credit Amount to satisfy, dollar-for-dollar, its payment obligations under this Section 4.1 until one hundred percent (100%) of the Rent Credit Amount has been so applied, whether under this Ground Lease or any other lease between the Landlord and the Tenant or its Affiliate.

(b) Commencing on the fifth (5th) anniversary of the Ground Lease Commencement Date and on every fifth (5th) year thereafter during the Term, the Rent shall be adjusted upward by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment during any Adjustment Period (as defined below) of greater than [***]. The period of time from the Ground Lease Commencement Date through the date five years thereafter, and each five (5) year period thereafter, shall be defined herein as an “Adjustment Period.” Any upward adjustment based on a CPI Percentage Increase (as defined below) to any payment under this Ground Lease shall hereinafter be referred to as a “CPI Adjustment.”

(c) Pursuant to the terms of the Option Agreement, the Tenant has paid to the Landlord (i) the sum of [***] as advance Rent (the “Advance Rent Payment Aggregate Amount”) and (ii) the sum of [***] to extend the closing date thereunder.

(d) The Landlord and the Tenant agree that the Rent shall constitute all charges applicable for the use, enjoyment and operation of the Site, but the Rent is not intended to include, and will not include, reduce or abate, any taxes, tariffs, fees or charges that may be assessed by the Landlord, as a political subdivision of the State of Louisiana, pursuant to Applicable Laws, against vessels calling at Facility or for such vessels using any other facilities or waterways that are subject to the Landlord’s jurisdiction. Any such taxes, tariffs, fees or charges will be separately assessed, charged and paid by the vessel’s owners or charterers in accordance with the Landlord’s assessments of same, all in accordance with Applicable Laws. The Tenant shall not be responsible for any such taxes, tariffs, fees or charges, rather the Landlord shall be solely responsible for dealing directly with such vessel owners and charterers regarding such taxes, tariffs, fees or charges. Nothing in this Ground Lease is intended to relieve any vessel owner of any obligation

 

11


it may have under Applicable Laws to pay taxes, tariffs, fees or charges legally assessed by the Landlord for use of the of waterways within Landlord’s jurisdiction. Any taxes, tariffs, fees or charges assessed by the Landlord for use of the waterways within the Landlord’s jurisdiction shall be assessed and applied uniformly, on a non-discriminatory manner, against all vessels within the Landlord’s jurisdiction and any such taxes, tariffs, fees or charges assessed by the Landlord on such vessels shall not exceed market rates for such taxes, tariffs, fees or charges assessed by similar ports within the United States.

(e) In addition to any taxes, tariffs, fees, or charges assessed pursuant to Section 4.1(d), a fixed fee of [***] (the “Throughput Fee”) may be assessed by the Landlord, as additional Rent, for the export of LNG from the Facility, commencing in the first month following the commercial operation date of the Facility. For the purposes of this Section 4.1(e), LNG imported or exported means the quantity of LNG (expressed in dekatherms) loaded onto or unloaded from an LNG vessel at the Facility, as measured and reported by the Tenant to the U.S. Department of Energy (“DOE Reporting”), and excludes LNG used or consumed (including as marine fuel) by the LNG vessel in the loading or unloading process and LNG that unloading process and LNG that evaporates during transfer (known as “boil off”). Any Throughput Fee, to the extent assessed by the Landlord, will be separately paid on a monthly basis by the Tenant to the Landlord based on LNG quantities imported to or exported from the Facility as set forth in the relevant DOE Reporting. Commencing on the fifth (5th) anniversary of the Ground Lease Commencement Date, and each Adjustment Period thereafter, the Throughput Fee shall be adjusted by a percentage equal to the greater of [***] or the CPI Percentage Increase, but in no event to exceed an adjustment during any Adjustment Period of greater than [***]. For the avoidance of doubt, the Tenant shall not be obligated to pay the Throughput Fee with respect to any natural gas used by the Facility to produce electrical power for LNG production or for electrical power generated at the Facility and sold or transmitted into the electrical grid.

4.2 CPI Adjustment. If the CPI Percentage Increase (as defined below) is more than [***] for the relevant Adjustment Period, then the Rent payable during that Adjustment Period shall be adjusted upward by a percentage equal to the CPI Percentage Increase (as defined below) applicable to such Adjustment Period, but not to exceed an adjustment during any Adjustment Period of greater than [***]. The term “Consumer Price Index” shall mean the unadjusted Consumer Price Index for All Urban Workers, U.S. City Average, All Items, 1982-84=100, calculated and published by the United States Department of Labor, Bureau of Labor Statistics. The “CPI Percentage Increase” shall mean, with respect to any Adjustment Period, [***]. For the avoidance of doubt, no CPI Adjustment shall be made to any payment due under this Ground Lease for any Adjustment Period if the result of such CPI Adjustment would be to (a) reduce the amount of such payment to an amount that is less than the amount of such payment due for the

 

12


immediately preceding Adjustment Period or (b) to raise the amount of such payment to an amount that is greater than [***]. For illustrative purposes only, [***]. The CPI Percentage Increase for any Adjustment Period shall be calculated by the Tenant, and the Tenant shall deliver written notice to the Landlord describing such calculation in reasonable detail (a “CPI Notice”) no later than thirty (30) days after the commencement of any Adjustment Period. If the Landlord disagrees with the Tenant’s calculation of the CPI Percentage Increase, then the Landlord shall deliver to the Tenant written notice, describing the basis for such disagreement in reasonable detail (a “CPI Disagreement Notice”), not later than sixty (60) days after delivery of the CPI Notice. If the Landlord fails to deliver a CPI Disagreement Notice within sixty (60) days after delivery of any CPI Notice, then the Landlord shall be conclusively deemed to have agreed with the calculation of the CPI Percentage Increase set forth in such CPI Notice.

 

 

4.3 Due Date. Except as otherwise provided in this Ground Lease, all Rent payments shall be due in advance on the 1st calendar day of each month and payable by the 15th calendar day of each month during the entire term of this Ground Lease. If the 15th calendar day of a month falls on a weekend day or holiday, then Rent shall be payable on the following Business Day.

4.4 Business Days. If the day on which any amount hereunder is due and payable is not a Business Day, such amount shall not be due and payable until the next following Business Day.

4.5 Place of Payment. Except as otherwise provided herein, Rent shall be payable by wire transfer via the wire instructions set forth below, or to such other place as the Landlord may specify and the Tenant deem acceptable, as hereinafter provided, from time to time:

Bank Name: [***]

Bank Address: [***]

Account Name: [***]

Account No.: [***]

Routing No.: [***]

5. Net Lease; Taxes and Utility Expenses.

5.1 Net Lease. This Ground Lease is a net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs, if any, of every kind and nature whatsoever relating to the Site except as expressly otherwise provided in this Ground Lease.

5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and Governmental Approval fees applicable to the Facility during the Term.

 

13


(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on, or related to, the Improvements, but not the underlying real (immovable) property comprising the Site, during the Term and the Removal Period (prorated on the basis of a 365-day year to account for any fractional portion of a fiscal tax year included in the Term or Renewal Term at the commencement or expiration thereof). The Landlord shall promptly provide all Property Tax bills to the Tenant when they become available. The Tenant shall use commercially reasonable efforts to cause Property Tax bills on or related to the Improvements to be delivered directly to the Tenant. Upon the latter of (i) one (1) month after receipt of such Property Tax bill, whether from the Landlord or otherwise, or (ii) the due date of any such Property Taxes on or related to the Improvements, the Tenant shall provide the Landlord with reasonable written evidence from the Plaquemines Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

(c) Landlord shall pay or cause to be paid when due any and all Property Taxes on or related to the underlying real (immovable) property, but not the Improvements, comprising the Site. The Tenant shall have no liability to pay or cause to be paid such Property Taxes, except as set forth in Section 5.2(b).

(d) The Landlord shall provide written notice to the Tenant of its receipt of any oral or written notice of any audit, examination, claim or assessment relating to Property Taxes on or related to the Improvements within ten (10) Business Days following receipt of such notice. Tenant may, as the sole owner of the Improvements, contest, resolve, appeal, defend and settle any such audit, examination, claim or assessment, as applicable, all at the Tenant’s direction.

5.4 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost, electricity, telephone, water, sewerage, gas, and other utility services to the Site; provided, however, the Landlord shall cooperate, and to the extent reasonably needed, facilitate the contracting of any easements, servitudes and/or rights of way, and grant easements, servitudes and rights of way in accordance with Section 2.2, as required by the Tenant for such utility connections and/or services.

 

6.

Tenant and Landlord Improvements.

6.1 Landlord’s Improvements. “Landlord’s Improvements” are any and all improvements to the immovable property of the Site and any and all movable property in existence on the Site at the time of the Ground Lease Commencement Date. There are no Landlord’s Improvements on the Site.

6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install on the Site, the Facility (which may be constructed in two phases) and any Improvements during the Term as long as the changes, alterations and/or Improvements comply with Applicable Laws and the terms of this Ground Lease. During the Term, the Tenant shall be permitted to make any changes, improvements or alterations to the Site, the Facility and any Improvements to the Site as long as the changes, alterations and/or Improvements comply with Applicable Laws and the terms of this Ground Lease.

 

14


6.3 Governmental Approvals. The Landlord will cooperate and assist (and never oppose) the Tenant in obtaining any and all Governmental Approvals deemed necessary by the Tenant for the Facility and all other Improvements to the Site, including with respect to Governmental Approvals from the Federal Energy Regulatory Commission and the Department of Energy.

6.4 Tenant’s Property. The Tenant’s Property shall at all times be and remain the sole property of the Tenant.

6.5 Maintenance of Improvements.

(a) Tenant’s Obligation to Maintain. During the Term, the Tenant will keep in reasonably good state of repair the Facility, the Improvements, open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Site by the Tenant, and the Tenant will, in its sole discretion as to the methodology and cost, repair such property as often as may be necessary in order to keep the Facility and Improvements in reasonably good repair and condition, except as set forth in Section 6.5(b).

(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease, the Landlord has no obligation to maintain the Site, Improvements and/or Landlord’s Improvements (if any) during the Initial Term. The Landlord further agrees that there will be no Landlord improvements on the Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

7. Tenant’s Surrender of Site.

7.1 Surrender at End of Ground Lease. Subject to Section 6.4 and subject and subordinate to Section 23 and the rights of any Leasehold Lender under any Leasehold Mortgage, the Tenant shall and will on the last day of the Term, surrender and deliver the Site to the Landlord, in as good a condition as is reasonably practicable (except as provided in Section 6.5 or Section 13), excepting normal wear and tear. If this Ground Lease is terminated for any reason or upon the expiration of the Term, the Tenant shall in good faith promptly proceed with (i) any removal of the Facility and any and all Improvements and (ii) restoration, if any, of the Site to its condition prior to construction of the Facility and/or Improvements. During the Removal Period, the Tenant shall have all access rights to the Site that are necessary to remove any and all of the Tenant’s Property, including the Facility and/or Improvements, and the Tenant shall continue to maintain insurance pursuant to Section 10.2 and pay Rent in accordance with Article 4. During the Removal Period, the Tenant shall also comply as required by any federal regulations of the Federal Energy Regulatory Commission or any other federal authority with respect to the Facility on the Site.

 

15


7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date, the Tenant shall assume full dominion, control and responsibility for the Site, except to the extent specifically provided herein, to the extent provided under LSA – R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real or personal property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its Affiliates, and their respective officers, representatives, agents, or employees or the Landlord’s misrepresentations or its breach of or default under this Ground Lease.

7.3 Holding Over. Except for a Removal Period, if the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, and shall not constitute a renewal or extension of the Term.

8. Use.

8.1 Permitted Uses; Compliance with Laws; Permits. The Tenant may use the Site (a) for the construction, ownership, operation, and maintenance of the Facility (which may be constructed in two phases), the Improvements and any ancillary or related uses, and (b) with the prior written consent of the Landlord, which consent shall not be unreasonably withheld, conditioned or delayed, for any and all other uses desired by the Tenant in compliance with all Applicable Laws. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the construction and maintenance of the Facility, the Improvements and/or for the Tenant’s use or activities on the Site. Except for Landlord’s limited obligation to pay Property Taxes, if any, on the underlying real (immovable) property comprising the Site as provided in Section 5.2, the Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Facility and the Improvements and security of the Site, including the timely filing, implementation, and enforcement of any security plan required by Applicable Laws. Any fine or penalty imposed by any Governmental Authority solely caused by the failure of the Tenant to comply with this Section 8.1, including any fine or penalty imposed upon the Landlord as owner of the Site as solely caused by the failure of the Tenant to comply with this Section 8.1, shall be the sole responsibility of the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall indemnify and hold harmless the Landlord from the payment of any such fine or penalty, and the Tenant shall either pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord or promptly defend the Landlord against any fine or penalty imposed by the Governmental Authority.

 

16


8.2 Use of Water Frontage. The Tenant shall have any and all rights, including any and all riparian rights, to use any and all of the water frontage and water bottom of the Site, including the Landlord’s Improvements (if any) and the area between the water frontage of the Site to the Mississippi River, for mooring of vessels and/or for any and all other uses allowed under Applicable Laws; and the Landlord shall not have the right to use the water frontage of the Site, including all aforementioned areas, for mooring of vessels or any other uses without the prior written consent of the Tenant. It is expressly understood that the Tenant’s consent shall be given or withheld in the Tenant’s sole discretion, and if granted, would be in accordance with any security plan of the Tenant.

8.3 Dirt Moving Activities; Permits; Timber.

(a) The Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Site, to the Site, and from portions of the Site to other portions of the Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Site and may do so in its discretion. The Tenant shall have the right to remove soil and spoil from, and to add fill to, the Site and to dredge the slip and turning basin and dredge and widen the Mississippi River, and deposit the dredge spoils on the Site (as allowed by Applicable Laws), in each case in connection with the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of the Facility, and for the purpose of constructing, creating, expanding, operating and maintaining a marine terminal and ship turning basin. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Site, including for the Facility, any Improvements, reclamation of lands, erosion control, attainment of spoil, servitudes and/or rights of way; provided that all costs associated with such efforts shall be the responsibility of the Tenant. Except only as provided in Section 8.3(b), the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Site, and all other rights on and to the Site. Any activities of the Landlord and/or its lessees or assignees or any other party shall not adversely affect the Site or the Facility or interfere with the Tenant’s operations or rights under this Ground Lease in any way. Nothing herein is intended to preclude the Landlord, from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation. The Tenant may freely remove any timber that is standing or lying on the Site as the Tenant deems necessary for the Tenant’s intended use of the Site. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights below the surface of the Site.

(b) To the extent the Landlord holds any rights to oil, gas, sulfur or other minerals (“Minerals”) in the Site, the Landlord shall retain such rights during the Term and hereby waives any and all rights of the Landlord, its Affiliates and their respective lessees or assignees to use the surface of the Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the Term, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means consistent with the terms and conditions of this Section 8.3(b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface

 

17


Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any way.

8.4 Crossing. The Landlord shall assist the Tenant in the Tenant’s efforts to develop, at the Tenant’s cost, any roads and/or crossings or other Improvements across the Site and boundary lines of the Site to the adjacent land, including relocation of utilities, providing culverts for storm water drainage, and any other Improvements. The Tenant or others, excluding the Landlord, will pay the cost to relocate or modify the infrastructure for these roads and/or crossings and/or other Improvements.

8.5 Pipelines; Rights of Way. If at any time the Tenant notifies the Landlord that the Facility requires a pipeline and/or pipeline servitude for the development, construction or operation of the Facility at the Site (other than the servitude described in Section 8.6), the Landlord shall, with respect to its own real (immovable) property, grant, at no additional cost to the Tenant, and, with respect to any other property, use commercially reasonable efforts to assist Tenant in having the applicable landowners and Governmental Authorities to grant, the pertinent approvals to achieve, construct and operate and maintain the pipeline and/or pipeline right of way, as directed and on such terms and conditions as reasonably requested by the Tenant; provided, that, with respect to any such pipeline and/or pipeline servitude off-Site but on the Landlord’s real (immovable) property, the Tenant shall pay fair market price for any such servitude and Landlord shall reasonably cooperate with the Tenant to site, such pipeline servitude to the extent that such pipeline servitude does not adversely affect or interfere with any existing utilities, then contemplated utilities, then contemplated roadway, rail or other transportation facilities associated with the Industrial Zone or the development, construction or operation of any portion of the Industrial Zone development contemplated by Landlord. Any off-site pipeline servitude agreement shall be in writing and shall otherwise be on mutually acceptable terms and conditions.

8.6 Servitude. Upon the Tenant’s request, the Landlord agrees to execute a servitude with the Tenant’s Affiliate, Venture Global Gator Express, LLC, pursuant to which such Affiliate may permanently locate up to two 42” natural gas pipelines on the Site for interconnection with the Facility in the form set forth hereto as Exhibit 7 (the “Gator Express Servitude”).

 

9.

Indemnification.

9.1 Tenant’s General Agreement to Indemnify. The Tenant releases the Landlord, its officers, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including reasonable attorney’s fees, witness fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Landlord Indemnitee arising out of (i) the use or occupancy of the Site by the Tenant, its officers, representatives, agents, and employees, (ii) the construction or operation of

 

18


the Facility and the Improvements by the Tenant, its officers, representatives, agents, and employees, (iii) any claim arising out of the use, occupancy, construction or operation of the Site by the Tenant, its contractors, officers, representatives, agents, and employees, and (iv) activities on or about the Site by the Tenant, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, operation, maintenance, or repair of the Facility, the Improvements, or the Site by the Tenant, its officers, representatives, agents, and employees; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Landlord Indemnitee shall be excluded from this indemnity. This Section 9.1 shall include within its scope any and all claims or actions for wrongful death. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9.2 and 9.4 and not this Section 9.1.

9.2 Tenant’s Environmental Indemnification.

(a) For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with all Environmental Laws applicable to the Tenant, including those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Tenant agrees to indemnify and hold harmless the Landlord Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, reasonable attorney, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Site or any violation of any Environmental Law with respect to the Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, and maintenance activities or facilities and not caused by the Landlord’s Activities or Landlord’s Improvements.

(b) If Hazardous Substances become present or are discharged onto the Site in violation of applicable Environmental Laws as a result of the Tenant’s use or occupancy of the Site during the Term, the Tenant shall so notify the Landlord in writing promptly after the Tenant’s discovery thereof, and the Tenant shall have a reasonable period of time to undertake, at its own expense, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority. Notwithstanding any right of Tenant to temporarily store or discharge Hazardous Substances on or at the Site if in compliance with Environmental Laws, Tenant shall remove or remediate all Hazardous Substances located on or at the Site at the expiration or earlier termination of the Term. The Landlord shall have a reasonable right of participation in the removal or remediation activities, including the right to (i) receive copies of material reports, work plans and correspondence relating to the removal or remediation activities, (ii) the right to review and comment on draft reports and work plans (and all reasonable comments shall be accepted by the controlling Party), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.2(b) shall not supersede or diminish the provisions or the Tenant’s obligations under Section 9.2(a).

 

19


9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including reasonable attorney’s fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Site by the Landlord, its officers, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Site by the Landlord, its officers, representatives, agents, and employees, and (iii) activities on or about the Site by the Landlord, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope any and all claims or actions for wrongful death, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.2 and 9.4 and not this Section 9.3.

9.4 Landlord’s Environmental Indemnification.

(a) For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord, including those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including reasonable attorneys accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person (including a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances, or (ii) any actual or alleged violation of Environmental Laws, in the case of each of subclauses (i) and (ii), where the presence, discharge or release of such Hazardous Substances or violation of Environmental Law arises or occurs (1) at, on or from the Site on or prior to the Ground Lease Commencement Date or (2) at, on or from the Site or any other site as a result of or relating to the Landlord’s Activities or facilities or Landlord’s Improvements, whether before, on or after the Ground Lease Commencement Date, or (iii) the Landlord’s breach of the covenant set forth in this Section 9.4 or (iv) any environmental condition of contamination on the Site or any violation of any Environmental Law with respect to the Site to the extent occurring after the Ground Lease Commencement Date and caused by the Landlord’s Activities or facilities.

 

20


(b) If Hazardous Substances become present or are discharged onto the Site as a result of the Landlord’s Activities or otherwise exist at the Site on or prior to the Ground Lease Commencement Date, the Tenant shall so notify the Landlord in writing promptly after the Tenant’s discovery thereof, and the Landlord shall have a reasonable period of time to undertake, at its own expense, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority, except that such removal or remediation shall not unreasonably interfere with the construction, operation, or maintenance of the Facility and/or unreasonably interfere with the Improvements by the Tenant. The Tenant shall have the right to undertake such removal and remediation activities in its discretion, and the Landlord shall reimburse the Tenant (or the Tenant may offset against Rent) for its reasonable and necessary documented costs therefor within thirty (30) days after receipt of an invoice by the Landlord (including any costs associated with the work stoppage or interference with the ability of any Facility Contractor to perform its respective obligations under the Facility Contracts (including mobilization and de-mobilization costs, suspension costs, storage costs, rescheduling penalties, and all other direct and indirect costs incurred by the Tenant or any Facility Contractor (and its respective subcontractors) as a result of any delay caused by such removal and/or remediation activities)). The Party not controlling the remediation under this Section 9.4(b) shall have a reasonable right of participation in the removal or remediation activities, including the right to (i) receive copies of material reports, work plans and correspondence relating to the removal or remediation activities, (ii) the right to review and comment on draft reports and work plans (and all reasonable comments shall be accepted by the controlling Party), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.4(b) shall not supersede or diminish the provisions or the Landlord’s obligations under Section 9.4(a).

9.5 Survival of Indemnities. The foregoing indemnities shall survive the Term and any Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

9.6 Environmental Condition. The Tenant represents and warrants to the Landlord that it has commissioned and completed, as of the Ground Lease Commencement Date, a Phase 1 environmental site assessment with respect to the Site prepared by Environmental Resources Management, Inc., dated June 2020, updated November 2020 and July 2021, a copy of which has been provided to the Landlord in respect of the environmental condition of the Site as of the date of such assessment (the “Environmental Assessment”). Landlord and Tenant acknowledge that the Environmental Assessment did not identify any “recognized environmental conditions” (as that term is defined in American Society for Testing and Materials Standard E1527-13, “Standard Practice for Environmental Site Assessments: Phase I Environmental Site Assessment Process”) in association with the Site.

10. Insurance.

10.1 Pre-FID Tenant’s Insurance.

(a) At all times prior to FID, at its sole expense, the Tenant shall maintain or cause to be maintained:

 

21


(i) for the protection of the Tenant and the Landlord, commercial general liability insurance applying to the use and occupancy of the Site and the business operated by the Tenant on the Site, which shall be written to apply to bodily injury (including death), property damage and personal injury losses, and shall be endorsed to include the Landlord as an additional insured. Such insurance shall have a minimum combined single limit of liability of at least $[***] per occurrence and a general annual aggregate limit of at least $[***]. The Tenant may elect to be self-insured in amounts greater than those minimum limits;

(ii) policies of insurance covering the Tenant’s Property in an amount reasonably determined by the Tenant, providing protection against any peril included within the classification “all risk coverage” or “causes of loss special form” (as such terms are used in the State of Louisiana), including vandalism and malicious mischief. The Tenant shall be entitled to all proceeds of such insurance, and the value of the Tenant’s Property shall be determined by the Tenant; and

(iii) policies of insurance from the Tenant’s pre-FID construction contractors meeting the requirements set forth in Exhibit 9.

10.2 Post-FID Tenant’s Insurance. Prior to FID, the Tenant and the Landlord will cooperate in good faith to develop and agree to the levels and insurance coverages applicable from and after FID that are appropriate for an infrastructure facility such as the Facility that is: (a) under full construction, including insurance policies to be obtained by the Tenant’s construction contractors; and (b) appropriate once the Facility is operational (including any appropriate escalation clauses for the recommended coverages), and in each case based upon input from a nationally recognized insurance advisor in the LNG industry jointly appointed by the Parties at the Tenant’s expense; provided that such insurance coverages are no less comprehensive than the insurance coverages recommended by the insurance advisor to the Financing Parties.

10.3 Insurance Providers. All insurance required to be carried by the Tenant under this Ground Lease shall be issued by insurance companies rated A-VII or better by A.M. Best, and reasonably acceptable to the Landlord. Each insurance policy carried by the Tenant in accordance with this Ground Lease shall include a waiver of the insurer’s rights of subrogation to the extent necessary to give effect to the release and shall name the Landlord as an additional named insured. The foregoing waiver shall be effective whether or not a waiving party shall obtain and maintain the insurance which such waiving party is required to obtain and maintain pursuant to this Ground Lease.

10.4 Landlord’s Insurance. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Site and/or any activities of the Landlord with respect to the Site in its reasonable business discretion. The Landlord may elect to be self-insured.

 

22


11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. The Landlord shall not create or permit to be created or to remain in connection with the Site, or the Facility, the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of the Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Site or upon the Landlord’s interest in the Site or upon the Tenant’s interest in its leasehold of the Site, in accordance with Section 11.2. Notwithstanding the foregoing, the Landlord may, and with prior written consent of the Tenant, which consent shall not be unreasonably withheld, conditioned or delayed, grant from time to time to other lessees of the Landlord within the Industrial Zone any easements, servitudes, and rights of way on the areas of the Site that are not located within the Site Wall for access and electricity, communications, gas, water, sewer and other utility lines, roadways or other transportation facilities from and to the leasehold estates of such other lessees over land and waterways within the areas of the Site not located within the Site Wall sufficient to permit the other lessees of the Landlord to accomplish their purposes in connection with their respective projects; provided, that such easements, servitudes, or rights of way do not adversely affect or interfere with the Facility, the Improvements, any expansion of the Facility or the Improvements contemplated by the Tenant, or the construction, ownership, operation, or maintenance thereof, and the Landlord shall pay any out-of-pocket costs and expenses incurred by the Tenant in granting such easements, servitudes and rights of way. The Landlord and the Tenant shall cooperate to ensure, to the extent possible, that any such easements, servitudes, and rights of way minimize interference with the development of the Site. If requested by the Landlord, the Landlord and the Tenant shall cooperate to relocate, to the extent possible, any such easements, servitudes or rights of way on the areas of the Site not located within the Site Wall; provided, that any such relocation does not adversely affect or interfere with the Facility, the Improvements, any expansion of the Facility or the Improvements contemplated by the Tenant, or the construction, ownership, operation or maintenance thereof.

11.2 Discharge of Liens.

(a) If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facility, the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facility, the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

(b) If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such Lien by deposit or by bonding proceedings. Any amount so paid by the non-responsible Party and all costs and expenses incurred by the non-responsible Party in connection therewith,

 

23


including reasonable attorneys’ fees together with interest thereon at one percent (1%) per annum above the Wall Street Journal Prime Rate of interest published from time to time in the Wall Street Journal, from the respective dates of the non-responsible Party’s making of the payment or incurring of the cost and expense, shall constitute either additional Rent payable by the Tenant under this Ground Lease or an offset against Rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for (or offset against Rent) the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Site, including any taxes owed by the Landlord and other liabilities, obligations and/or debts owed to laborers, vendors, materialmen, and other service providers; provided, that the Landlord shall be in default of such obligations and the Tenant shall first provide reasonable prior notice to the Landlord of the Tenant’s intention to satisfy such obligations.

 

12.

Entry on Premises by Landlord, Etc.

The Landlord and its representatives shall have no right to enter the Site, except: (1) as specifically authorized from time to time in advance in writing by the Tenant, or (2) in the event of an emergency, caused by casualty, natural disaster, or accident; provided the Landlord shall use reasonably practicable efforts to provide notice to the Tenant prior to entering the Site in the event of such emergency. If the Landlord, outside of an emergency as set forth in the preceding sentence, desires to inspect the Site, the Landlord shall provide the Tenant a written notice no less than five (5) Business Days prior to the date of such proposed entry. The Tenant may deny entry onto the Site if the Tenant reasonably believes that entry onto the Site by the Landlord and its representative poses a risk to (a) the health and/or safety of the Tenant’s or its contractor’s employees or personnel or to the Landlord or its representative or (b) the security, operation and/or maintenance of the Facility or the Improvements. If and when entry onto the Site is granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of the Tenant. Such entry on the Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions such that access to certain sections of the Site will be restricted. In no event shall any limitation or notice provision of this Section 12 prevent or impede entry onto the Site by the Landlord, any Affiliate or any Governmental Authority due to the emergency and necessary exercise of any valid police power under Applicable Laws; provided, that the Landlord shall use reasonable best efforts to preclude any interference with the Facility, and shall provide reasonable prior notice to the Tenant thereof unless such entry is necessary to prevent or respond to any imminent threat to life or damage to property.

 

24


13. Destruction by Fire or Other Casualty.

If the Facility or any Improvements erected on the Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the willful misconduct of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Facility or the Improvements. In the event that the Tenant so decides not to restore or reconstruct the Facility or the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove any ruins or rubble remaining on the Site at the Tenant’s sole cost and expense.

14. Assignment; Subleasing; Right of First Refusal.

14.1 Restrictions on Landlord. The Landlord shall not assign this Ground Lease or sell the Site, in whole or in part, (including by transfer of control or otherwise) without the prior written consent of the Tenant or having complied with Section 14.3, as applicable, which consent shall not be unreasonably withheld, conditioned, or delayed; provided, however, it shall not be unreasonable for the Tenant to withhold consent if (a) the Landlord requests to assign this Ground Lease or sell the Site, in whole or in part, to any Person, or any Affiliate of such Person, that is a direct or indirect competitor of the Tenant or any of its Affiliates, or (b) the Landlord requests to assign this Ground Lease or sell the Site, in whole or in part, to any Person that does not have substantially similar jurisdiction, authority, rights, and privileges as the Landlord as a political subdivision of the State of Louisiana. The Landlord covenants, represents and warrants as a condition of this Ground Lease as of the Ground Lease Commencement Date that the Landlord has no present intention to assign this Ground Lease or sell the Site, in whole or in part, during the Term.

14.2 Restrictions on Tenant. Subject to the provisions of Section 23, the Tenant shall not assign this Ground Lease, in whole or in part, without the prior written consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least thirty (30) days prior written notice of any proposed assignment and any other information that the Landlord may reasonably request; provided the Tenant is in possession of, or Tenant can reasonably acquire, such information, together with a copy of the proposed assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing, including to a Leasehold Lender, (ii) to a Leasehold Lender or any purchaser upon a foreclosure of a Leasehold Mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a Leasehold Mortgage, (iii) to any Affiliate or member of the Tenant; provided such Affiliate or member owns and/or operates the Facility (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, or (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder. The Tenant shall not sublease all or any portion of the Site without the prior written consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned.

 

25


14.3 Right of First Refusal. During the Term, the Landlord may not transfer a portion of the Site and may only transfer the entire Site through a bona fide sale in exchange for a sum certain of money. If the Landlord, during the Term, makes a bona fide offer to sell or receives a bona fide offer from a third party to buy or acquire (individually and collectively a “Bona Fide Offer”) all or any portion of the Site separately or as a part of a larger parcel of which the Site is a part, the Landlord will promptly, within ten (10) Business Days of such making or receipt, give written notice to the Tenant of the terms of the Bona Fide Offer made or received, including the cash price attributable to the Site. If the sale is a tract of which the Site is a part, then the cash price attributable to the Site will be that part of the cash price multiplied times a fraction, the denominator of which is the total number of acres in the Site and the numerator of which is the total number of acres in the larger tract to be sold. The notice shall also state the other terms and conditions of the proposed sale and the Landlord’s willingness to sell for that cash price and on those terms. Upon receiving the notice, the Tenant may exercise the right, in the manner specified below, to purchase either the property described in the Bona Fide Offer or the Site (or part thereof) at the stated cash price in the Bona Fide Offer.

14.4 Exercise of Right of First Refusal. If the Tenant elects to purchase the property or Site described in the Bona Fide Offer under the provisions of Section 14.3, the Tenant must notify the Landlord of such election, doing so in writing delivered to the Landlord within thirty (30) Business Days after the date of the Landlord’s written notice to the Tenant of the Bona Fide Offer. If the Tenant elects to refuse the Bona Fide Offer, the Tenant need take no action whatsoever; further, if the Tenant fails to deliver to the Landlord a notice of the Tenant’s election within the time required for such notice, the Tenant will be deemed to have refused the Bona Fide Offer. If the Tenant refuses, or is deemed to have refused, the Bona Fide Offer, the Landlord is free to sell the property pursuant to the Bona Fide Offer subject to this Ground Lease, any Leasehold Mortgage, any New Lease (as defined in Section 23.9(a)) and any Non-Disturbance Agreement (as defined in Section 23.9(c)) and continuation of the leasehold interest created by this Ground Lease and any New Lease (as defined in Section 23.9(a)).

14.5 Continuation of Right. If for any reason the Site is not sold by the Landlord following a bona fide offer from a third-party, the right of first refusal granted and described in the preceding Sections 14.3 and 14.4 shall continue in full force and effect, on the same terms and conditions.

14.6 Conflict with Applicable Laws. If, and to the extent, the right of first refusal granted by the Landlord to the Tenant pursuant to Section 14.3 is prohibited by Applicable Laws, the rights and obligations granted and described in the preceding Sections 14.3 and 14.4 shall be inoperative.

15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of fifteen (15) days after written notice thereof from the Landlord to the Tenant.

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15.1(a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the

 

26


Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Site or discharge from the Site shall not constitute an Event of Default.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default, the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the Tenant shall be liable for such reasonable damages unless such Event of Default is reasonably remedied in a timely manner and all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default, together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and payable, and all costs and expenses reasonably incurred by or on behalf of the Landlord as a result of the Event of Default, including reasonable attorneys’ fees, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective and is not valid if the Landlord does not give prior written notice to the Tenant pursuant to Section 15.1.

(b) Landlord’s Remedies; Right to Cure Tenant’s Event of Default. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default that is not fully cured under Section 15.2(a), in addition to all other remedies available to the Landlord, the Landlord may terminate this Ground Lease by written notice to the Tenant. Upon the occurrence of an Event of Default of the Tenant which is not cured or which Tenant has not commenced to cure within sixty (60) days as provided in Section 15.2(a), then, subject to the prior written consent of any Leasehold Lender under Section 23, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others to cure the Event of Default. The Tenant shall be responsible for all costs, including attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord.

 

27


15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, following any Removal Period, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Site to the Landlord, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Site and may have, hold, and enjoy the Site; and (ii) all obligations of the Tenant hereunder for additional Rent or any portion thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. In the event of any termination, the Landlord shall be under a duty to seek a successor tenant. If the Landlord obtains a successor tenant during what would have been the remainder of the Term or any Removal Period, the Tenant shall receive a credit for rentals collected from said successor tenant for the remaining Term. If no successor tenant is obtained, the Tenant shall be liable for Rent obligations otherwise provided for in this Ground Lease.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

15.5. Tenant Security. The Tenant shall provide in favor of the Landlord a Letter of Credit, in the amount of [***] (the “Tenant Security”); provided, that no such Tenant Security shall be required unless and until one hundred percent (100%) of the Rent Credit Amount has been applied in accordance with Section 4.1. Any Tenant Security provided pursuant to this Section 15.5 shall automatically expire on the earlier to occur of (i) FID and (ii) the fifth (5th) anniversary of the Ground Lease Commencement Date. The Landlord shall have the right to draw upon or make a claim against the Tenant Security upon the occurrence and continuation of an Event of Default resulting from the Tenant’s failure to make any payments owing under this Ground Lease, after the giving of any required notice hereunder and the expiration of any applicable cure period, including the cure periods set forth in Section 15.2, in each case, for an amount not to exceed the amount the non-payment of which gave rise to the Event of Default. All amounts drawn and actually paid under the Tenant Security shall be deemed applied to the applicable outstanding unpaid amount and upon such payment, if the amount paid is sufficient to satisfy in full the non-payment, the Event of Default giving rise to the Landlord’s right to make a claim against the Tenant Security shall be deemed to be cured. Any Letter of Credit posted by the Tenant as Tenant Security shall permit the Landlord to draw the entire amount available thereunder if such Letter of Credit is not renewed or replaced at least thirty (30) calendar days prior to its stated expiration date. The Tenant shall have the right, in its sole discretion, to replace the Tenant Security with the same form of the Tenant Security at any time.

15.6. Financial Condition. The Tenant represents and warrants that, as of FID, the Tenant will have sufficient equity capital and debt commitments from the Financing Parties to: (i) complete the construction of the Facility; (ii) commence commercial operations of the Facility; and (iii) commence and continue the timely payment of Rent until the commencement of commercial operations of the Facility.

 

28


16. Events of Default of the Landlord.

16.1 Landlord Event of Default; Right to Cure. If default shall be made by the Landlord in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, and such default shall continue for a period of sixty (60) days after written notice thereof from the Tenant to the Landlord specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Landlord fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Landlord within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence), a “Landlord Event of Default” shall be deemed to have occurred hereunder.

16.2 Tenant’s Remedies; Cure. In the event of a Landlord Event of Default, in addition to all other remedies available to the Tenant, the Tenant may terminate this Ground Lease by written notice to the Landlord. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof, and shall be immediately payable to the Tenant. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default.

16.3 Tenant’s Right to Cure Landlord Event of Default. Upon the occurrence of a Landlord Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others, purchasing the required goods or services and procuring necessary insurance. The Landlord shall be responsible for all costs including attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

17. Mutual Obligations.

17.1 Late Charges; Interest. If any Rent or any other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of ten (10) days after receipt of written notice, such sum shall bear a late charge equal to one percent (1.0%) of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

 

29


17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise (excluding, however, specific performance against the Tenant) and the exercise or beginning of the exercise by the Parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by facsimile or United States registered or certified mail, return receipt and signature requested, postage prepaid, to the Parties at the following numbers and addresses:

 

To the Tenant:

   Venture Global Plaquemines LNG, LLC 1001
   19th Street North
   Suite 1500
   Arlington, VA 22209
   Attention: [***]
   Facsimile: [***]
   Email: [***]

To the Landlord:

   Plaquemines Port, Harbor and Terminal District
   8056 Highway 23, Third Floor
   Belle Chasse, LA 70037
   Attn: [***]
   Telephone: [***]
   Facsimile: [***]
   Email: [***]

 

30


With a copy to:

   Plaquemines Port, Harbor and Terminal District
   8056 Highway 23, Third Floor
   Belle Chasse, LA 70037
   Attn: [***]
   Telephone: [***]
   Facsimile: [***]
   Email: [***]

With a copy to:

   Dwyer, Cambre, and Suffern, L.L.C.
   3000 West Esplanade Ave., Ste. 200
   Metairie, LA 70002
   Attention: [***]
   Telephone: [***]
   Facsimile: [***]
   Email: [***]

or to such other numbers or addresses as any of above designated recipients may from time to time designate by written notice to the other designated recipients hereto at least fifteen (15) days in advance of an effective date stated therein.

18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mail, return receipt and signature requested, postage prepaid.

19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable enjoyment of the Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Site during the Term and any Removal Period without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord, subject to the Permitted Exceptions (as defined by the Option Agreement). This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow industrial use of the remainder of its property adjacent to the Site.

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that: (i) it is the sole owner of good, marketable, fee simple title to all of the Site; (ii) the Site is subject to no Liens, privileges, encumbrances, defects in title, servitudes, easements, restrictions, dedications, leases, mineral leases, reservations or other exceptions to title, other than those Permitted Exceptions (as defined by the Option Agreement) existing on the Ground Lease Commencement Date (without limiting the Landlord’s obligations under Article 11); (iii) during the term hereof it shall not encumber the Site; (iv) it is authorized to make this

 

31


Ground Lease for the term hereof; (v) the provisions of this Ground Lease do not and will not conflict with or violate any of the provisions of existing agreements between the Landlord and any third party; and (vi) the Landlord will deliver the Site free of all tenants and occupants and claims thereto. For the avoidance of doubt, the Tenant represents and warrants to the Landlord that, except as set forth on Exhibit 10, all Title Objections (as defined by the Option Agreement) were satisfactorily addressed during the Title Review Period (as defined by the Option Agreement).

20. Eminent Domain.

20.1 Complete Condemnation. If, during the term hereof, the whole of the Site shall be taken under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking) by any public or private authority, then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided that the Tenant shall share in the condemnation award as provided herein. The Tenant may continue to occupy the Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Site from and after the date of such taking.

20.2 Partial Condemnation. If, during the term hereof, any public or private authority shall, under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking), makes a taking resulting in the reduction of the surface area of the Site by fifteen percent (15%) or more, or of fifteen percent (15%) or more of the value of the Facility, the Improvements or the Landlord’s Improvements, or resulting in material interference to the Facility or the Improvements or the Tenant’s ability to use in a commercially reasonable manner the remainder of the Site, the Facility, the Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of the exercise of its election within one-hundred twenty (120) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2, the term hereof shall cease and terminate as of the last day of the calendar month in which such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant, and the Tenant shall share in the condemnation award as provided herein.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the term hereof shall continue in full force and effect, and the monthly Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

 

32


20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete taking pursuant to Section 20.1, the Tenant will be entitled to receive the portion of the condemnation award (or settlement) attributable to (i) the value of the Facility and Improvements and Landlord’s Improvements, and fixtures and other property located on the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, plus (iii) other compensation or benefits paid as a consequence of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking (if any such compensation or benefits are paid by the applicable taking authority) and the Landlord shall be entitled to recover that portion of the condemnation award (or settlement) fairly attributable to the value of the land taken. In the event the Tenant’s Property, the Improvements or the Facility are not taken, the Tenant shall not be entitled to any portion of the award, and in the event no Landlord’s property is taken, the Landlord shall not be entitled to any portion of the award unless the Tenant elects to terminate this Ground Lease pursuant to Section 20.2, in which event the award or settlement shall be fairly allocated to compensate Landlord for its loss in accordance with Applicable Laws. In the event of a partial taking of the Improvements, the Tenant’s Property and/or Facility not resulting in a termination of this Ground Lease pursuant to Section 20.2, the entire award or settlement shall be paid to the Tenant. In the event of a partial taking of the Site, the Tenant will be entitled to receive the portion of the award attributable to (i) the value of the portion of the Facility, Improvements and the Tenant’s Property located in the portion of the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, plus (iii) damage to the remaining Facility, and the Tenant will promptly restore the remaining portion of the Facility to the extent of the award payable to the Tenant. Nothing contained herein shall prohibit the Tenant’s claiming relocation damages or damages for lost profits or loss of leasehold advantage against the taking authority in any appropriate proceeding.

21. Temporary Taking or Other Deprivation.

If, during the term hereof, (i) less than all of the Landlord’s title to all or any portion of the Site is taken for temporary use or occupancy, or (ii) any public or private authority takes any action not resulting in a taking of all or any portion of the Site but resulting in a right to compensation therefor, such as changing of the grade of any street upon which the Site abuts, then, except as otherwise provided in Section 20, the Tenant shall be entitled to make claim for, recover, and retain all awards, whether pursuant to judgment, agreement, or otherwise, recoverable in connection therewith.

22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure; provided that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

 

33


23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section 23 shall govern and control.

23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage, or any agent or trustee therefor, that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant. The term “Leasehold Mortgage” shall mean, at any point in time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Site and this Ground Lease. It is acknowledged and agreed that, during the Term, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the Term, the Tenant shall provide the Landlord with written notice of the identity, contact information and address for each Leasehold Lender (or the agent authorized to act on behalf of the Leasehold Lender), such notice to be provided to the Landlord by the Tenant promptly after the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

23.2 Right to Perform for Tenant; Right to Cure.

(a) In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and the Landlord shall accept such performance by Leasehold Lender with the same force and effect as if furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing. Should Leasehold Lender fail to exercise its right to cure as provided above, the Landlord may terminate this Ground Lease by written notice to the Leasehold Lender.

(b) If any default in the performance of an obligation of the Tenant under this Ground Lease is not susceptible to being cured by Leasehold Lender, the Landlord shall have no right to terminate this Ground Lease with respect to such default and such default shall be deemed waived for the benefit of Leasehold Lender only; provided that:

 

34


(i) Leasehold Lender shall have commenced to cure (i) any other non-payment default of the Tenant that is susceptible to being cured by Leasehold Lender and (ii) any default in the payment of any portion of Rent, in each case, within the time periods prescribed under Section 23.2(a);

(ii) Leasehold Lender (or its designee) shall have commenced to acquire the Tenant’s interest in this Ground Lease and the Site or to commence foreclosure or other appropriate proceedings under the Leasehold Mortgage within the time periods prescribed under Section 23.2(a);

(iii) if Leasehold Lender (or its designee) shall acquire the Tenant’s interest in this Ground Lease and/or the Site, Leasehold Lender (or its designee) shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition; and

(iv) if any third party shall, by foreclosure or dation en paiement under the Leasehold Mortgage or by assignment or other transfer from Leasehold Lender, acquire the Tenant’s interest in and to the Site under this Ground Lease, such third party shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by a third party with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition.

However, if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then notwithstanding any provision in this Section 23 to the contrary, the Landlord may exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’s prior written consent, and any such action taken without Leasehold Lender’s consent shall not be binding on the Tenant or the Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

 

35


23.4 Delivery of Notices. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been delivered to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in writing to the Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’s interests in the Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including the acquisition of the Tenant’s interest in this Ground Lease and the Site created thereby in a transaction described in this Section 23 or the taking of possession of the Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender; provided that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Site.

23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2, the purchaser at any sale of this Ground Lease and the interests in and to the Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Site thereby created under any instrument of assignment or transfer in lieu of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Site thereby created.

 

36


23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, substantially all, or any part of the Site or the Tenant’s Facility. Rent shall continue to be due and payable as set forth in this Ground Lease.

23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent domain proceeding of all, substantially all, or any part of the Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Facility, the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Site created by this Ground Lease and the value of the leasehold improvements located on the Site, up to an amount equaling the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Facility and/or the Tenant’s interest in, under and to this Ground Lease; provided that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under Applicable Laws to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this Ground Lease. In the event of a taking of a portion of the Site, the Rent shall be reduced pro rata based upon the portion of the Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease.

23.9 New Direct Lease.

(a) If this Ground Lease is canceled or terminated for any reason (except in connection with a Bankruptcy Proceeding, for which the provisions of Section 23.10 are hereby agreed upon by the Landlord and the Tenant), and provided that Leasehold Lender has (i) commenced to cure and continues diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, and (ii) cured any payment default in respect of any portion of Rent, the Landlord hereby agrees that the Landlord shall, upon Leasehold Lender’s written election within one hundred twenty (120) days of such

 

37


cancellation or termination, promptly enter in a new, direct lease with Leasehold Lender (or its nominee or any other party which Leasehold Lender may designate, including the Tenant) with respect to the Site on the same terms and conditions as this Ground Lease (a “New Lease”), it being the intention of the parties to preserve this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Said New Lease shall be superior to all rights, liens and interests intervening between the date of this Ground Lease and the granting of the New Lease and shall be free of any and all rights of the Tenant under this Ground Lease.

(b) The Tenant and the Landlord acknowledge and agree that Leasehold Lender shall have the right to encumber such direct New Lease and the estate created thereby with a deed of trust or a mortgage (as the case may be) on the same terms and with the same lien priority as the Leasehold Mortgage, it being the intention of the parties to preserve the priority of the Leasehold Mortgage, this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. If this Ground Lease is rejected, cancelled or terminated for any reason and Leasehold Lender, its nominee or a designee of Leasehold Lender enters into a direct lease with the Landlord with respect to the Site, the Landlord hereby agrees that it will execute such documents as Leasehold Lender may require in order to ensure that the new direct lease provides for customary leasehold mortgagee protections, including protections similar to those contained herein.

23.10 Bankruptcy. In the event of a proceeding under the United States Bankruptcy Code (Title 11 U.S.C.) as now or hereafter in effect (a “Bankruptcy Proceeding”):

(a) If this Ground Lease is rejected in connection with a Bankruptcy Proceeding by the Tenant or a trustee in bankruptcy (or other party to such proceeding) for the Tenant, such rejection shall be deemed an assignment by the Tenant to the Leasehold Lender of the Tenant’s Property and all of the Tenant’s interest under this Ground Lease, and this Ground Lease shall not terminate and the Leasehold Lender shall have all rights and obligations of the Tenant as if such Bankruptcy Proceeding had not occurred, unless Leasehold Lender shall reject such deemed assignment by notice in writing to the Landlord within thirty (30) days following rejection of this Ground Lease by the Tenant or the Tenant’s trustee in bankruptcy. If any court of competent jurisdiction shall determine that this Ground Lease shall have been terminated notwithstanding the terms of the preceding sentence as a result of rejection by the Tenant or the trustee in connection with any such proceeding, the rights of Leasehold Lender to a New Lease from the Landlord pursuant to Section 23.9 hereof shall not be affected thereby.

(b) In the event of a Bankruptcy Proceeding against the Landlord:

(i) If the bankruptcy trustee, the Landlord (as debtor-in-possession) or any party to such Bankruptcy Proceeding seeks to reject this Ground Lease pursuant to United States Bankruptcy Code §365(h)(1), the Tenant shall not have the right to treat this Ground Lease as terminated except with the prior written consent of Leasehold Lender and the right to treat this Ground Lease as terminated in such event shall be deemed assigned to Leasehold Lender, whether or not specifically set forth in the Leasehold Mortgage, so that the concurrence in writing of the Tenant and the Leasehold Lender shall be required as a condition to treating this Ground Lease as terminated in connection with such Bankruptcy Proceeding.

 

38


(ii) Unless this Ground Lease is treated as terminated in accordance with Section 23.10(b)(i), then this Ground Lease shall continue in effect upon all the terms and conditions set forth herein, including Rent, but excluding requirements that are not then applicable or pertinent to the remainder of the Term. Thereafter, the Tenant or its successors and assigns shall be entitled to any offsets against Rent payable hereunder for any damages arising from such bankruptcy, to the extent the Tenant’s operation of business has been materially interfered with, and any such offset properly made shall not be deemed a default under this Ground Lease. The lien of the Leasehold Mortgage shall extend to the continuing possessory rights of the Tenant following such rejection with the same priority as it would have enjoyed had such rejection not taken place.

23.11 Estoppel Certificates; Non-Disturbance Agreements.

(a) Within twenty (20) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel”) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under this Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant hereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy hereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that each of this Ground Lease and the Non-Disturbance Agreement (as defined in Section 23.11(c)), true, correct copies of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, have not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Term is scheduled to expire, (vii) as to the Landlord’s power and authority to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or Applicable Laws or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease and any Non-Disturbance Agreement, there do not exist any other agreements

 

39


concerning the Site or this Ground Lease, whether oral or written, to which the Landlord is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the Landlord Estoppel, the present lessor under this Ground Lease and owns good and indefeasible title to the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (xix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

(b) Within twenty (20) days following Leasehold Lender’s or the Landlord’s written request, the Tenant shall provide Leasehold Lender with an estoppel certificate (the “Tenant Estoppel”) which shall certify to such requesting Leasehold Lender (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Landlord of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Landlord of any other conditions required under this Ground Lease, (iii) as to any existing default of the Landlord under this Ground Lease, or alternatively that the Landlord is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Landlord hereunder, and as to any existing event or condition in existence as of the date of the Tenant Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Tenant to terminate, accelerate, or modify this Ground Lease or exercise any other remedy hereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Tenant, (v) that this Ground Lease, a true and correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Term is scheduled to expire, (vii) as to the Tenant’s power and authority to execute the Tenant Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Tenant asserting that (A) this Ground Lease violates any agreement or Applicable Laws or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Tenant from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties, or other sums, whether

 

40


or not constituting rent, due and owing as of the date of the Tenant Estoppel and as to any rent that the Tenant has prepaid under this Ground Lease, (xii) that, except for this Ground Lease, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which the Tenant is a party (other than those set forth on a schedule to the Tenant Estoppel (provided that Landlord shall only be bound by written agreements signed by Landlord as provided by Section 24.6 herein)), (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Tenant Estoppel, (xiv) that the Tenant is, as of the date of the Tenant Estoppel, the present lessee under this Ground Lease and holds a valid leasehold interest in the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Tenant has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Tenant’s interest in the Site, other than those set forth on a schedule to the Tenant Estoppel, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Tenant is a party or by which the Tenant is otherwise bound affecting the Tenant’s interest in and to the Site, (xvii) that the Tenant has not commenced any action or sent any notice to the Landlord for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Tenant is not, as of the date of the Tenant Estoppel, entitled to terminate, cancel, modify, or surrender this Ground Lease, and (xviii) as to such other matters related to this Ground Lease as such Leasehold Lender may reasonably determine from time to time.

(c) Within twenty (20) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall enter into a non-disturbance agreement with Leasehold Lender or its designee, in the form attached hereto as Exhibit 4 (a “Non-Disturbance Agreement”).

23.12 No Merger. There shall be no merger of this Ground Lease or any interest in this Ground Lease or of the interests in and to the Site created thereby with the fee estate in the Site, by reason of the fact that this Ground Lease or such interest therein, may be directly or indirectly held by or for the account of any person who shall hold any interest in the fee estate in the Site, nor shall there be such a merger by reason of the fact that all or any part of the interests in and to the Site created by this Ground Lease may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any interest in the fee estate in the Site or any interest of the Landlord under this Ground Lease.

23.13 Landlord’s Recognition of Tenant. The Landlord hereby recognizes the Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that the Tenant acquired its interest in this Ground Lease and in and to the Site in accordance with the terms of this Ground Lease.

23.14 Agreement to Amend. The Landlord recognizes the importance of the Tenant’s ability to obtain Leasehold Mortgages, and that the provisions of this Ground Lease may be subject to the approval of a Leasehold Lender. If any Leasehold Lender should require, as a condition to such financing, any reasonable modifications of this Ground Lease, whether for purposes of clarifying the provisions of this Ground Lease or to include provisions then customary for leasehold financing transactions, the Landlord agrees to execute the appropriate amendments to this Ground Lease; provided, however, that no such modification shall, to the detriment of the Landlord, impair any of the Landlord’s rights, as reasonably determined by the Landlord or increase any of the Landlord’s obligations, as reasonably determined by the Landlord, under this Ground Lease.

 

41


23.15 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

23.16 Subordination of Landlord’s Lien. The Landlord hereby subordinates any lien or privilege it may have on any movables found from time to time in or upon the Site, including Landlord’s privileges pursuant to La. Civil Code articles 2707, et seq., to any Leasehold Lender’s rights under this Section 23 and the lien of any Leasehold Mortgage.

23.17 Tenant Security. The Landlord’s right to draw upon the Tenant Security pursuant to Section 15.5 shall not be limited by this Section 23.

24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

24.2 Successors. The covenants, agreements, terms, provisions, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties hereto.

24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

 

42


24.6 No Oral Change or Termination. This Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties hereto with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, including the Option Agreement, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

24.9 Dispute Resolution.

(a) If a dispute between the Parties arises out of, under or in connection with this Ground Lease, including its interpretation, performance, enforcement, termination, validity or breach, any Party shall provide notice of such dispute to the other Party. Within fifteen (15) days after the receipt of such notice, or such longer time as mutually agreed to by the Parties, the Parties shall meet, and the meeting shall be attended by representatives of the senior management of the Parties with decision-making authority regarding such dispute, to attempt in good faith to negotiate a resolution to such dispute.

(b) If, after the management settlement conference set forth in Section 24.9(a), the Parties to the dispute have not succeeded in negotiating a resolution of the dispute, then either Party to the dispute may refer the matter to litigation. Completion of the management settlement conference set out in Section 24.9(a) shall be a condition precedent to initiating such litigation; provided, however, the failure of a Party to participate in the management settlement conference set forth in Section 24.9(a) shall not prevent the other Party from referring a dispute to litigation.

(c) In case of any litigation between the Parties hereto regarding the subject matter hereof, the losing Party shall pay all reasonable costs and expenses (including reasonable attorneys’ fees) of the prevailing Party. The venue of any litigation shall be solely in Plaquemines Parish, Louisiana.

 

43


24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

24.11 Authority. The Landlord and the Tenant each represents and warrants that it has the authority to enter into this Ground Lease, that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date,

(a) the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 5, evidencing its authority to execute and perform under this Ground Lease and (b) the Landlord shall deliver to the Tenant a resolution in the form attached hereto as Exhibit 6, evidencing its authority to execute and perform under this Ground Lease.

24.12 No Waiver. Neither acceptance of Rent by the Landlord nor failure by the Landlord to complain of any action, non-action or default of the Tenant, whether singular or repetitive, shall constitute a waiver of any of the Landlord’s rights hereunder. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Site and no agreement to accept a surrender of the Site shall be valid unless it is in writing and signed by the Landlord.

24.13 Limited Recourse. The Landlord agrees that the sole recourse of the Landlord for any damages or liabilities due by the Tenant hereunder shall be limited to the assets of the Tenant, without recourse individually or collectively to the members or the Affiliates of the Tenant, the Leasehold Lenders or their respective directors, officers, agents, members, shareholders, managers, partners, employees or representatives, subject, however, to recourse and recovery under the Tenant Security.

24.14 Further Assurances. In connection with this Ground Lease and the transactions contemplated hereby, each Party shall execute and deliver any additional documents and instruments and perform any additional acts that may be necessary or appropriate on a commercially reasonable basis to effectuate and perform the provisions of this Ground Lease and those transactions, including in connection with the requests of any Financing Parties or Leasehold Lender.

24.15 Brokers and/or Real Estate Agents. The Landlord and the Tenant each represent to the other party that they have dealt with no brokers in connection with the negotiation, execution and/or delivery of the Option Agreement or this Ground Lease, and that no party is entitled to any broker’s commission, finder’s fee or similar payment with respect to this Ground Lease arising from the representing party’s actions. If any other person shall assert a claim to a finder’s fee, brokerage commission or other compensation on account of alleged employment as finder or broker in connection with this transaction, the party against whom the purported finder or broker is claiming shall indemnify, defend and hold the other party harmless from and against any such claim and any and all costs, expenses and liabilities incurred in connection with such claim or any action or proceeding brought thereon, including reasonable attorneys’ fees and court costs in defending such claim.

 

44


24.16 Legal Relationships; Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. There is no third party beneficiary of this Ground Lease, except as provided in Section 23.15 and any rights of a Leasehold Lender as provided herein. This Ground Lease is the product of the Parties joint negotiation and equal drafting thereof. The language of this Ground Lease shall be construed as a whole according to its fair meaning and not construed strictly for or against any of the Parties pursuant to any statue, case law or rule of interpretation or construction to the contrary.

24.17 Memorandum of Lease. The Parties hereto agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’s interest hereunder; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease. The Parties further agree to execute, and Tenant agrees to cause to be properly recorded, a memorandum of termination of this Ground Lease following any early termination hereof.

[Remainder of page left intentionally blank; signatures on following pages]

 

45


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

/s/ Robert L. Seegers, Jr.

WITNESS Robert L. Seegers, Jr.

     

LANDLORD:

 

PLAQUEMINES PORT HARBOR &

TERMINAL DISTRICT

      By:   

/s/ Maynard J. Sanders

/s/ Niki W. Kelly

      Name: Maynard J. Sanders
WITNESS Niki W. Kelly       Title: Executive Director

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the Parish of Jefferson and State of Louisiana, personally came and appeared Maynard J. Sanders, who, after being sworn by me, did execute this agreement on the 19th day of July, 2021 at Metairie, State of Louisiana.

    J. Kendal Rathburn    

NOTARY PUBLIC

 

/s/ John Thomson

WITNESS John Thomson

    

TENANT:

 

VENTURE GLOBAL PLAQUEMINES

LNG, LLC

       

/s/ Sean Cammilleri

     By:   

/s/ Keith Larson

WITNESS Sean Cammilleri      Name: Keith Larson
     Title: Secretary

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 14th day of July, 2021 at Arlington, State of Virginia.

    Annette B. Thrasher    

NOTARY PUBLIC

 

1


LIST OF EXHIBITS

 

Exhibit 1-A     Legal Description of Site
Exhibit 1-B    Boundary Survey
Exhibit 2-A    Facility Description
Exhibit 2-B    Plot Plan
Exhibit 3    Industrial Zone
Exhibit 4    Form of Non-Disturbance Agreement
Exhibit 5    Tenant’s Resolution
Exhibit 6    Landlord’s Resolution
Exhibit 7    Form of Servitude
Exhibit 8    New Highway Route
Exhibit 9    Contractor Insurance Requirements
Exhibit 10    Title Objections
Exhibit 11    Form of Irrevocable Letter of Credit for Lease

 

1


EXHIBIT 1-A

LEGAL DESCRIPTION OF THE SITE

TRACT DR-5

A CERTAIN PARCEL OF LAND, together with and inclusive of batture and all batture rights, thereunto belonging or in anywise appertaining situated in the Parish of Plaquemines, State of Louisiana on the right descending bank of the Mississippi River, situated in Township 17 South, Range 25 East, Sections 1 and 2, and Township 17 South, Range 26 East, Sections 21 and 22, Deer Range Plantation, Plaquemines Parish, Louisiana and being more fully described as follows:

Commencing and Beginning at the point of intersection of the common line of Tract DR-1 and Tract DR-5 of Deer Range Plantation, with the northeasterly right of way of Louisiana State Highway Number 23, said point being marked with a 2 inch iron pipe and having a 1983 Louisiana State Plane Coordinate (South Zone) of X=3,738,050.70 feet and Y=405,989.68 feet; thence North 33 degrees 22 minutes 41 seconds East, along said common line to the point of intersection with the Mean Low Water Plane of the Mississippi River a distance of 1,020 feet, more or less;

Thence downriver along said Mean Low Water Plane of the Mississippi River to the point of intersection with the upriver line of parcel B-1, a distance of 7,105 feet, more or less;

Thence, South 4 degrees 45 minutes 47 seconds West along said upriver line of parcel B-1 to the point of intersection with the northerly line of the State of Louisiana Tract 1-2, a distance of 655 feet, more or less;

Thence along said northerly line of the State of Louisiana Tract 1-2 for the next three courses;

Thence North 85 degrees 14 minutes 09 seconds West to the point of curvature of a curve concave to the right, a distance of 2,223.67 feet;

Thence along said curve concave to the right having a radius of 2864.90 feet, a length of 926.69 feet and a chord bearing North 75 degrees 58 minutes 10 seconds West for a distance of 922.65 feet to the point of tangency;

Thence North 66 degrees 42 minutes 10 seconds West to the point of intersection with the common line of the State of Louisiana Tract 1-2 and the State of Louisiana Tract 1-1, a distance of 4,100.85 feet to a point;

Thence along the northerly line of the State of Louisiana Tract 1-1 for the next three courses;

Thence North 66 degrees 42 minutes 10 seconds West to the point of curvature of a curve concave to the left, a distance of 76.43 feet;

 

1


Thence along said curve concave to the left having a radius of 7529.44 feet, a length of 250.73 feet and a chord bearing North 67 degrees 39 minutes 01 second West for a distance of 250.72 feet to the point of tangency;

Thence North 68 degrees 35 minutes 53 seconds West a distance of 49.54 feet to a point;

Thence North 33 degrees 22 minutes 41 seconds East a distance of 146.56 feet to the point of intersection with the northeasterly right of way of Louisiana State Highway Number 23, and the

POINT OF BEGINNING.

All as more fully described in that certain Cash Sale to Plaquemines Port Harbor & Terminal District, recorded December 9, 2013 under File Number 2013-00005489, Book 1308, Page 52, Plaquemines Parish Clerk of Court’s Office, as corrected by that certain Act of Correction to Cash Sale recorded October 26, 2020 under File Number 2020-00004504, Book 1430, Page 970, Plaquemines Parish Clerk of Court’s Office

And

TRACT DR-3

A CERTAIN PARCEL OF LAND, together with and inclusive of batture and all batture rights thereunto belonging or in anywise appertaining situated in the Parish of Plaquemines, State of Louisiana on the right descending bank of the Mississippi River, situated in Township 17 South, Range 25 East, Sections 1, 2 and 3, Deer Range Plantation, Plaquemines Parish, Louisiana and being more fully described as follows:

Commencing as the point of intersection of the common line of Tract DR-1 and Tract DR-5 of Deer Range Plantation, with the northeasterly right of way of Louisiana State Highway Number 23, said point being marked with a 2 inch iron pipe and having a 1983 Louisiana State Plane Coordinate (South Zone) of X=3,738,050.70 feet and Y=405,989.68 feet; thence South 33 degrees 22 minutes 41 seconds West, along said common line a distance of 61.24 feet to the point of intersection with a line 50.00 feet northerly of the centerline of the old highway (southbound lane), said line being the southwesterly line of Tract DR-1; thence continuing South 33 degrees 22 minutes 41 seconds West to the point of intersection with the northeasterly line of the State of Louisiana Tract 1-1, a distance of 85.32 feet, thence continuing South 33 degrees 22 minutes 41 seconds West across State of Louisiana Tract 1-1, a distance of 81.36 feet to the point of intersection with the southwesterly line of said State of Louisiana Tract 1-1, said point also being the point of intersection with the common line of Tracts DR-2A and DR-3 and the POINT OF BEGINNING.

Thence South 59 degrees 39 minutes 03 seconds East, along the common line of said Tract 1-1 and DR-3, a distance of 115.82 feet to a point;

Thence South 66 degrees 42 minutes 54 seconds East, continuing along said common line of said Tract 1-1 and DR-3 to the point of intersection with the common line of said Tract 1-1 and the State of Louisiana Tract 1-2 distance of 272.80 feet.

 

2


Thence continuing South 66 degrees 42 minutes 54 seconds East, along the common line of said Tract 1-2 and DR-3, a distance of 2927.20 feet to a point.

Thence South 66 degrees 13 minutes 10 seconds East, continuing along said common line to the point of intersection with the common line of Tract DR-3 and DR-4, a distance of 1,044.29 feet.

Thence South 32 degrees 33 minutes 49 seconds West, along said common line to the point of intersection with the common line of Duckland, L.L.C. and Tract DR-3, a distance of 4,376.91 feet;

Thence North 77 degrees 09 minutes 29 seconds West, along said common line of Duckland, L.L.C. and Tract DR-3 a distance of 2,359.62 feet to a point.

Thence North 52 degrees 40 minutes 26 seconds West continuing along the common line of Duckland, L.L.C. and Tract DR-3 to the point of intersection with the common line of Tract DR-2A and DR-3, a distance of 2,153.48 feet.

Thence North 33 degrees 22 minutes 41 seconds East, a distance of 4,314.92 feet along said common line to the point of intersection with the common line of State of Louisiana Tract 1-1 and DR-3, and the POINT OF BEGINNING.

All as more fully described in that certain Cash Sale to Plaquemines Port Harbor & Terminal District, recorded December 9, 2013 under File Number 2013-00005489, Book 1308, Page 52, Plaquemines Parish Clerk of Court’s Office, as corrected by that certain Act of Correction to Cash Sale recorded October 26, 2020 under File Number 2020-00004504, Book 1430, Page 970, Plaquemines Parish Clerk of Court’s Office.

 

3


EXHIBIT 1-B

BOUNDARY SURVEY

[Omitted]


EXHIBIT 2-A

FACILITY DESCRIPTION

[Omitted]


EXHIBIT 2-B

PLOT PLAN

[Omitted]


EXHIBIT 4

FORM OF NON-DISTURBANCE AGREEMENT

[Omitted]


EXHIBIT 5

TENANT’S RESOLUTION

[Omitted]


EXHIBIT 6

LANDLORD’S RESOLUTION

[Omitted]


EXHIBIT 7

FORM OF SERVITUDE

[Omitted]


EXHIBIT 8

NEW HIGHWAY ROUTE

[Omitted]


EXHIBIT 9

CONTRACTOR INSURANCE REQUIREMENTS

[Omitted]


EXHIBIT 10

TITLE OBJECTIONS

[Omitted]


EXHIBIT 11

FORM OF IRREVOCABLE LETTER OF CREDIT FOR LEASE

[Omitted]

Exhibit 10.55

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

STATE OF LOUISIANA

PARISH OF PLAQUEMINES

GROUND LEASE AGREEMENT

This GROUND LEASE AGREEMENT (this “Ground Lease”) is effective as of January 19, 2022 (the “Ground Lease Commencement Date”), by and between PLAQUEMINES LAND VENTURES, LLC, a Delaware limited liability company (the “Tenant”) and THE PLAQUEMINES PORT HARBOR AND TERMINAL DISTRICT, a political subdivision of the State of Louisiana (the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as a “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Plaquemines Parish, Louisiana, which comprises approximately five hundred twenty-three and 549/1000 (523.549) acres;

WHEREAS, the Tenant wishes to lease land owned by the Landlord to support the Tenant’s and its Affiliates business activities, including such uses as an equipment offloading area, marine terminal, parking or transportation center, construction laydown area, all in connection with the development, permitting, financing, construction, testing, commissioning and initial operation and/or maintenance of a natural gas liquefaction facility by the Tenant’s Affiliate (the “Plaquemines LNG Project”), and such other ancillary and/or related uses permitted by this Ground Lease; and

WHEREAS, in accordance with the above, the Tenant has executed this Ground Lease and offers fair value to the Landlord as cause and consideration for this Ground Lease.

NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this Ground Lease, and the Parties herein covenant and agree as follows:

1. Definitions and Interpretation.

1.1 Definitions. As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

Affiliate” means, in respect of any Person, any other Person controlled by, controlling or under common control with such first Person. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of fifty percent (50%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.


Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Site.

Bankruptcy Proceeding” has the meaning set forth in Section 23.10.

Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in New York, New York are authorized or required by law to close.

Corps” has the meaning set forth in Section 8.2(a).

Environmental Assessment” has the meaning set forth in Section 9.6.

Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Laws or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Laws relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

Event of Default” has the meaning set forth in Section 15.1.

Facility” means a natural gas liquefaction facility, which may be constructed in two phases, each having a nameplate capacity of ten (10) million metric tonnes per annum of LNG.

FID” means that all conditions precedent set forth in the loan documents entered into by the Tenant or its Affiliates for the purposes of financing the Facility have been satisfied or waived and the Financing Parties party thereto have disbursed the initial loans thereunder.

Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Facility or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders.

Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include, but not be limited to, the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, droughts, floods, washouts, explosions, breakage or accident or necessity of repairs to machinery or equipment or lines of pipe; (ii) weather related events affecting an entire geographic region; (iii) acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, terrorism, discovery of burial grounds or human remains or legally protected artifacts, insurrections or wars; and (iv) governmental actions such as necessity for compliance with any court order, law, statute, ordinance, regulation, or policy having the effect of law promulgated by a Governmental Authority having jurisdiction. “Force Majeure” shall not include (i) the failure or interruption of performance by the Tenant’s engineering, procurement and construction contractor for the Plaquemines LNG Project or any subcontractors of such contractor, except to the extent caused by an event of Force Majeure; or (ii) the failure or interruption of performance by the suppliers to the Plaquemines LNG Project, except to the extent caused by an event of Force Majeure.

 

2


Governmental Approval” means any authorization, waiver, consent, approval, license, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority.

Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

Ground Lease” has the meaning set forth in the Preamble hereof.

Ground Lease Commencement Date” has the meaning set forth in the Preamble hereof.

Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

 

3


Hazardous Substances Law” means any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Laws or similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent it relates to the handling of and exposure to hazardous or toxic materials or similar substances.

Improvements” means any and all improvements made by the Tenant to the Site to support the Tenant’s and its Affiliates’ business activities, including such uses as an equipment offloading area, marine and trucking receipt, delivery and servicing facilities (including piers, marine terminals, bulkheads, wharfs, docks, inlets, wetslips, moonpools, moorings and jetties), temporary parking or temporary transportation center, construction laydown area, all in connection with the development, permitting, financing, construction, testing, commissioning and initial operation of a natural gas liquefaction facility.

Landlord” has the meaning set forth in the Preamble hereof.

Landlord Estoppel” has the meaning set forth in Section 23.11(a).

Landlord Event of Default” has the meaning set forth in Section 16.1.

Landlord Indemnitee” has the meaning set forth in Section 9.1.

Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, affiliates, invitees, agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Site and/or Landlord’s Improvements.

Landlord’s Improvements” has the meaning set forth in Section 6.1.

Lease Year” means a period of twelve (12) consecutive full calendar months. The first Lease Year shall begin on the Ground Lease Commencement Date. Each succeeding Lease Year shall commence upon the anniversary of the first day of the previous Lease Year.

Leasehold Lenders” has the meaning set forth in Section 23.1.

Leasehold Loan” has the meaning set forth in Section 23.1.

Leasehold Mortgage” has the meaning set forth in Section 23.1.

Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

Minerals” has the meaning set forth in Section 8.2(b).

 

4


New Lease” has the meaning set forth in Section 23.9(a).

Non-Disturbance Agreement” has the meaning set forth in Section 23.11(c).

Party” or “Parties” has the meaning set forth in the Preamble hereof.

Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

Plaquemines LNG Project” has the meaning set forth in the recitals.

Property Taxes” means all real (immovable) and personal (moveable) property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

Removal Period” means the maximum of a six (6) month period of time that is required by the Tenant to remove any and all of the Tenant’s Property from the Site in accordance with Section 7.1.

Rent” has the meaning set forth in Section 4.1(a).

Site” means the real (immovable) property of approximately five hundred twenty- three and 549/1000 (523.549) acres described in the legal description set forth in Exhibit 1-A, and illustrated by the boundary survey attached as Exhibit 1-B, which real (immovable) property is owned by the Landlord.

Surface Waiver” has the meaning set forth in Section 8.2(b).

Tenant” has the meaning set forth in the Preamble hereof.

Tenant Estoppel” has the meaning set forth in Section 23.11(b).

Tenant Indemnitee” has the meaning set forth in Section 9.3.

Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Site by or on behalf of the Tenant, including any Improvements.

Term” has the meaning set forth in Section 3.1.

1.2 Interpretation. Unless the context otherwise requires:

 

5


(a) Words singular and plural in number will be deemed to include the other and pronouns having a masculine or feminine gender will be deemed to include the other;

(b) Any reference to this Ground Lease or any other contract or agreement in respect of the Site means such agreement and all schedules, exhibits and attachments thereto as may be amended, supplemented or otherwise modified and in effect from time to time, and shall include a reference to any document which amends, modifies or supplements it, or is entered into, made or given pursuant to or in accordance with its terms;

(c) The terms “hereof,” “herein,” “hereby,” “hereto” and similar words refer to this entire Agreement and not any particular Section, subsection or other subdivision of, or Exhibit, appendix or schedule to, this Ground Lease;

(d) The terms “include” and “including” shall be construed as being at all times followed by the words “without limitation” or “but not limited to” unless the context specifically indicates otherwise;

(e) References to “Article,” “Section” or “Exhibit” are to this Ground Lease unless specified otherwise;

(f) References to any law, statute, rule, regulation, notification or statutory provision (including Applicable Laws) shall be construed as a reference to the same as it may have been, or may from time to time be, amended, modified or re-enacted;

(g) References to any Person shall be construed as a reference to such Person’s successors, heirs and permitted assigns; and

(h) The word “or” will have the inclusive meaning represented by the phrase “and/or”.

2. Lease of Ground Lease Premises and Additional Obligations.

2.1 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of Rent and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does hereby lease to the Tenant and the Tenant hereby leases from the Landlord, the Site and Landlord’s Improvements.

2.2 Servitudes. In addition, the Landlord shall grant from time to time to the Tenant and others designated by the Tenant (including any Affiliate of the Tenant) any temporary servitudes and rights of way reasonably requested by the Tenant on land owned or controlled by the Landlord for access and electricity, communications, gas, water, sewer and other utility lines, products and materials from and to the Site over land and waterways sufficient to access adjacent lands owned by the Landlord and to permit the Tenant to accomplish its purposes in connection with the Tenant’s use of the Site.

 

6


3. Term.

3.1 Term. The term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on July 19, 2026 (the “Term”).

3.2 Early Termination of Ground Lease. Notwithstanding Section 3.1, the Tenant may, in its sole discretion, terminate this Ground Lease prior to the expiration of the Term upon not less than one hundred twenty (120) days’ written notice to the Landlord. Following the date of such termination, neither the Landlord nor the Tenant shall have any further obligations or liability with respect to this Ground Lease, except (a) with respect to any obligations arising or accruing with respect to any period prior to such termination and (b) as set forth in Section 24.3.

4. Rent.

4.1 Rent.

(a) Commencing upon the Ground Lease Commencement Date, the ground rent for the Site shall be [***] per annum, payable in equal installments of [***] per month (the “Rent”). Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month; provided, however, that (x) the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first day of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; and (y) the last payment of Rent shall be in a prorated amount for the period of time between the immediately preceding first day of the month and the last day of the Term.

(c) The Landlord and the Tenant agree that the Rent shall constitute all charges applicable for the use, enjoyment and operation of the Site.

4.2 Due Date. Except as otherwise provided in this Ground Lease, all Rent payments shall be due in advance on the 1st calendar day of each month and payable by the 15th calendar day of each month during the entire term of this Ground Lease. If the 15th calendar day of a month falls on a weekend day or holiday, then Rent shall be payable on the following Business Day.

4.3 Business Days. If the day on which any amount hereunder is due and payable is not a Business Day, such amount shall not be due and payable until the next following Business Day.

4.4 Place of Payment. Except as otherwise provided herein, Rent shall be payable by wire transfer via the wire instructions set forth below, or to such other place as the Landlord may specify and the Tenant deem acceptable, as hereinafter provided, from time to time:

 

7


Bank Name: [***]

Bank Address: [***]

Account Name: [***]

Account No.: [***]

Routing No.: [***]

5. Net Lease; Taxes and Utility Expenses.

5.1 Net Lease. This Ground Lease is a net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs, if any, of every kind and nature whatsoever relating to the Site except as expressly otherwise provided in this Ground Lease.

5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and Governmental Approval fees applicable to the Site during the Term.

(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on, or related to, the Improvements, but not the underlying real (immovable) property comprising the Site, during the Term and the Removal Period (prorated on the basis of a 365-day year to account for any fractional portion of a fiscal tax year included in the Term or the Removal Period at the commencement or expiration thereof). The Landlord shall promptly provide all Property Tax bills to the Tenant when they become available. The Tenant shall use commercially reasonable efforts to cause Property Tax bills on or related to the Improvements to be delivered directly to the Tenant. Upon the latter of (i) one (1) month after receipt of such Property Tax bill, whether from the Landlord or otherwise, or (ii) the due date of any such Property Taxes on or related to the Improvements, the Tenant shall provide the Landlord with reasonable written evidence from the Plaquemines Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

(c) Landlord shall pay or cause to be paid when due any and all Property Taxes on or related to the underlying real (immovable) property, but not the Improvements, comprising the Site. The Tenant shall have no liability to pay or cause to be paid such Property Taxes, except as set forth in Section 5.2(b).

(d) The Landlord shall provide written notice to the Tenant of its receipt of any oral or written notice of any audit, examination, claim or assessment relating to Property Taxes on or related to the Improvements within ten (10) Business Days following receipt of such notice. Tenant may, as the sole owner of the Improvements, contest, resolve, appeal, defend and settle any such audit, examination, claim or assessment, as applicable, all at the Tenant’s direction.

 

8


5.3 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost, electricity, telephone, water, sewerage, gas, and other utility services to the Site; provided, however, the Landlord shall cooperate, and to the extent reasonably needed, facilitate the contracting of any temporary easements, servitudes and/or rights of way, and grant temporary easements, servitudes and rights of way in accordance with Section 2.2, as required by the Tenant for such utility connections and/or services.

6. Tenant and Landlord Improvements.

6.1 Landlord’s Improvements. “Landlord’s Improvements” are any and all improvements to the immovable property of the Site and any and all movable property in existence on the Site at the time of the Ground Lease Commencement Date, including existing piers and docks. The Landlord makes no representation as to the condition of the Landlord’s Improvements as of the Ground Lease Commencement Date.

6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install, or permit the construction and installation on the Site of, Improvements during the Term as long as the changes, alterations and/or Improvements comply with Applicable Laws and the terms of this Ground Lease. During the Term, the Tenant shall be permitted to make any changes, improvements or alterations to the Site, the Landlord’s Improvements and any Improvements to the Site, including the removal thereof, as long as the changes, alterations and/or Improvements comply with Applicable Laws and the terms of this Ground Lease.

6.3 Governmental Approvals. The Landlord will cooperate and assist (and never oppose) the Tenant in obtaining any and all Governmental Approvals deemed necessary by the Tenant for the Improvements to the Site.

6.4 Tenant’s Property. The Tenant’s Property shall at all times be and remain the sole property of the Tenant.

6.5 Maintenance of Improvements.

(a) Tenant’s Obligation to Maintain. During the Term, the Tenant will keep in reasonably good state of repair the Improvements (including any Landlord’s Improvements that the Tenant changes, improves or alters), open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Site by the Tenant, and the Tenant will, in its sole discretion as to the methodology and cost, repair such property as often as may be necessary in order to keep the Improvements in reasonably good repair and condition.

(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease, the Landlord has no obligation to maintain the Site, Improvements and/or Landlord’s Improvements (if any) during the Term. The Landlord further agrees that it will not construct or add any additional improvements on the Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

 

9


7. Tenant’s Surrender of Site.

7.1 Surrender at End of Ground Lease. Subject to Section 6.4 and subject and subordinate to Section 23 and the rights of any Leasehold Lender under any Leasehold Mortgage, the Tenant shall and will on the last day of the Term, surrender and deliver within six (6) months of the last day of the Term the Site to the Landlord, in as good a condition as is reasonably practicable (except as provided in Section 6.5 or Section 13), excepting normal wear and tear. If this Ground Lease is terminated for any reason or upon the expiration of the Term, the Tenant shall in good faith promptly proceed with (a) any removal of the Improvements and (b) restoration, if any, of the Site to its condition prior to the Tenant’s use of the Site; provided, that the Tenant (a) shall be under no obligation to restore any Landlord’s Improvements, without limiting its obligation to maintain as set forth in Section 6.5(a) and (b) at the Landlord’s request, the Tenant shall, subject to any restrictions upon the Tenant or its Affiliates relating to confidentiality, security, financing or Applicable Law, use good faith efforts to leave at the Site, and transfer ownership to the Landlord of, any Landlord’s Improvements that it has altered, changed or improved, in AS-IS condition without warranty or liability relating to subsequent performance or use. During the Removal Period, the Tenant shall have all access rights to the Site that are necessary to remove any and all of the Tenant’s Property, including the Improvements, and the Tenant shall continue to maintain insurance pursuant to Section 10.1 and pay Rent in accordance with Article 4.

7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date, the Tenant shall assume full dominion, control and responsibility for the Site, except to the extent specifically provided herein, to the extent provided under LSA – R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real or personal property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its Affiliates, and their respective officers, representatives, agents, or employees or the Landlord’s misrepresentations or its breach of or default under this Ground Lease.

7.3 Holding Over. Except for a Removal Period, if the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, and shall not constitute a renewal or extension of the Term.

8. Use.

8.1 Permitted Uses; Compliance with Laws; Permits. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the Tenant’s use or activities on the Site. Except as provided in Section 5.2, the Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Improvements and security of the Site, including the timely filing, implementation, and enforcement of any security plan required by

 

10


Applicable Laws. Any fine or penalty imposed by any Governmental Authority solely caused by the failure of the Tenant to comply with this Section 8.1, including any fine or penalty imposed upon the Landlord as owner of the Site as solely caused by the failure of the Tenant to comply with this Section 8.1, shall be the sole responsibility of the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall indemnify and hold harmless the Landlord from the payment of any such fine or penalty, and the Tenant shall either pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord or promptly defend the Landlord against any fine or penalty imposed by the Governmental Authority.

8.2 Dirt Moving Activities; Permits; Timber.

(a) The Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Site, to the Site, and from portions of the Site to other portions of the Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Site and may do so in its discretion. The Tenant shall have the right to remove soil and spoil from, and to add fill to, the Site for the purpose of constructing, creating, expanding, operating and maintaining a marine terminal or otherwise in connection with the development, construction, installation, use and initial operation and maintenance of the Facility. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Site, including for any Improvements, reclamation of lands, erosion control, attainment of spoil, servitudes and/or rights of way; provided that all costs associated with such efforts shall be the responsibility of the Tenant. Except only as provided in Section 8.2(b), the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Site, and all other rights on and to the Site. Any activities of the Landlord and/or its lessees or assignees or any other party shall not adversely affect the Site or interfere with the Tenant’s operations or rights under this Ground Lease in any way. Nothing herein is intended to preclude the Landlord, from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation. The Tenant may freely remove any timber that is standing or lying on the Site as the Tenant deems necessary for the Tenant’s intended use of the Site. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights below the surface of the Site.

(b) To the extent the Landlord holds any rights to oil, gas, sulfur or other minerals (“Minerals”) in the Site, the Landlord shall retain such rights during the Term and hereby waives any and all rights of the Landlord, its Affiliates and their respective lessees or assignees to use the surface of the Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the Term, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means consistent with the terms and conditions of this Section 8.2(b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Site and the Improvements or interfere with the Tenant’s operations or rights under this Ground Lease in any way.

 

11


8.3 Use of Water Frontage. The Tenant shall have any and all rights, including any and all riparian rights, to use any and all of the water frontage and water bottom of the Site, including the Landlord’s Improvements (if any) and the area between the water frontage of the Site to the Mississippi River, for mooring of vessels and/or for any and all other uses allowed under Applicable Laws; and the Landlord shall not have the right to use the water frontage of the Site, including all aforementioned areas, for mooring of vessels or any other uses without the prior written consent of the Tenant. It is expressly understood that the Tenant’s consent shall be given or withheld in the Tenant’s sole discretion, and if granted, would be in accordance with any security plan of the Tenant.

8.4 Access License Agreement. The Landlord hereby consents to the Tenant providing to the Tenant’s Affiliates, in connection with the Plaquemines LNG Project, non-exclusive access to the Site and entering into access license agreements with its applicable Affiliates with respect to such access; provided, that the foregoing shall not serve to modify or limit: (1) any of the Landlord’s or the Tenant’s rights and obligations under, or (2) the terms and conditions of, this Agreement. Upon Leasehold Lender’s or Tenant’s written request, Landlord shall provide Leasehold Lender or Tenant with an estoppel certificate consenting to such access and related access rights agreements. Tenant shall provide to Landlord notice within 30 days of any such granting of access to Tenant’s Affiliates, and/or any such entering into of access agreements.

9. Indemnification.

9.1 Tenant’s General Agreement to Indemnify. The Tenant releases the Landlord, its officers, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including reasonable attorney’s fees, witness fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Landlord Indemnitee arising out of (i) the use or occupancy of the Site by the Tenant, its officers, representatives, agents, and employees, (ii) the construction, maintenance, use, repair, or operation of the Improvements by the Tenant, its officers, representatives, agents, and employees, (iii) any claim arising out of the use or occupancy of the Site by the Tenant, its contractors, officers, representatives, agents, and employees, and (iv) activities on or about the Site by the Tenant, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, maintenance, or repair of the Improvements or the Site by the Tenant, its officers, representatives, agents, and employees; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Landlord Indemnitee shall be excluded from this indemnity. This Section 9.1 shall include within its scope any and all claims or actions for wrongful death. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9.2 and 9.4 and not this Section 9.1.

 

12


9.2 Tenant’s Environmental Indemnification.

(a) For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with all Environmental Laws applicable to the Tenant, including those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Tenant agrees to indemnify and hold harmless the Landlord Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, reasonable attorney, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Site or any violation of any Environmental Law with respect to the Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, and maintenance activities or use of the Site and not caused by the Landlord’s Activities or Landlord’s Improvements.

(b) If Hazardous Substances become present or are discharged onto the Site in violation of applicable Environmental Laws as a result of the Tenant’s use or occupancy of the Site during the Term, the Tenant shall so notify the Landlord in writing promptly after the Tenant’s discovery thereof, and the Tenant shall have a reasonable period of time to undertake, at its own expense, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority. Notwithstanding any right of Tenant to temporarily store or discharge Hazardous Substances on or at the Site if in compliance with Environmental Laws, Tenant shall remove or remediate all Hazardous Substances located on or at the Site at the expiration or earlier termination of the Term. The Landlord shall have a reasonable right of participation in the removal or remediation activities, including the right to (i) receive copies of material reports, work plans and correspondence relating to the removal or remediation activities, (ii) the right to review and comment on draft reports and work plans (and all reasonable comments shall be accepted by the controlling Party), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.2(b) shall not supersede or diminish the provisions or the Tenant’s obligations under Section 9.2(a).

9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including reasonable attorney’s fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Site by the Landlord, its officers, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Site by the Landlord, its officers, representatives, agents, and

 

13


employees, and (iii) activities on or about the Site by the Landlord, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope any and all claims or actions for wrongful death, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.2 and 9.4 and not this Section 9.3.

9.4 Landlord’s Environmental Indemnification.

(a) For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord, including those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including reasonable attorneys accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person (including a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances, or (ii) any actual or alleged violation of Environmental Laws, in the case of each of subclauses (i) and (ii), where the presence, discharge or release of such Hazardous Substances or violation of Environmental Law arises or occurs (1) at, on or from the Site on or prior to the Ground Lease Commencement Date or (2) at, on or from the Site or any other site as a result of or relating to the Landlord’s Activities or facilities or Landlord’s Improvements, whether before, on or after the Ground Lease Commencement Date, or (iii) the Landlord’s breach of the covenant set forth in this Section 9.4 or (iv) any environmental condition of contamination on the Site or any violation of any Environmental Law with respect to the Site to the extent occurring after the Ground Lease Commencement Date and caused by the Landlord’s Activities or facilities.

(b) If Hazardous Substances become present or are discharged onto the Site as a result of the Landlord’s Activities or otherwise exist at the Site on or prior to the Ground Lease Commencement Date, the Tenant shall so notify the Landlord in writing promptly after the Tenant’s discovery thereof, and the Landlord shall have a reasonable period of time to undertake, at its own expense, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority, except that such removal or remediation shall not unreasonably interfere with the Tenant’s use of the Site. The Tenant shall have the right to undertake such removal and remediation activities in its discretion, and the Landlord shall reimburse the Tenant (or the Tenant may offset against Rent) for its reasonable and necessary documented costs therefor within thirty (30) days after receipt of an invoice by the Landlord (including any costs associated with the work stoppage or interference with the ability of any contractor for the Plaquemines LNG Project to perform its respective contractual obligations (including mobilization and de-mobilization costs, suspension costs, storage costs,

 

14


rescheduling penalties, and all other direct and indirect costs incurred by the Tenant or any such contractor (and its respective subcontractors) as a result of any delay caused by such removal and/or remediation activities)). The Party not controlling the remediation under this Section 9.4(b) shall have a reasonable right of participation in the removal or remediation activities, including the right to (i) receive copies of material reports, work plans and correspondence relating to the removal or remediation activities, (ii) the right to review and comment on draft reports and work plans (and all reasonable comments shall be accepted by the controlling Party), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.4(b) shall not supersede or diminish the provisions or the Landlord’s obligations under Section 9.4(a).

9.5 Survival of Indemnities. The foregoing indemnities shall survive the Term and any Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

9.6 Environmental Condition. The Tenant represents and warrants to the Landlord that it has commissioned and completed, as of the Ground Lease Commencement Date, a Phase 1 environmental site assessment with respect to the Site prepared by Environmental Resources Management, Inc., dated January 2022, a copy of which has been provided to the Landlord in respect of the environmental condition of the Site as of the date of such assessment (the “Environmental Assessment”). Landlord and Tenant acknowledge that the Environmental Assessment did not identify any “recognized environmental conditions” (as that term is defined in American Society for Testing and Materials Standard E1527-13, “Standard Practice for Environmental Site Assessments: Phase I Environmental Site Assessment Process”) in association with the Site.

10. Insurance.

10.1 Pre-FID Tenant’s Insurance.

(a) At all times prior to FID, at its sole expense, the Tenant shall maintain or cause to be maintained:

(i) for the protection of the Tenant and the Landlord, commercial general liability insurance applying to the use and occupancy of the Site and the business operated by the Tenant on the Site, which shall be written to apply to bodily injury (including death), property damage and personal injury losses, and shall be endorsed to include the Landlord as an additional insured. Such insurance shall have a minimum combined single limit of liability of at least [***] per occurrence and a general annual aggregate limit of at least [***]. The Tenant may elect to be self-insured in amounts greater than those minimum limits;

(ii) policies of insurance covering the Tenant’s Property in an amount reasonably determined by the Tenant, providing protection against any peril included within the classification “all risk coverage” or “causes of loss special form” (as such terms are used in the State of Louisiana), including vandalism and malicious mischief. The Tenant shall be entitled to all proceeds of such insurance, and the value of the Tenant’s Property shall be determined by the Tenant; and

 

15


(iii) policies of insurance from the Tenant’s pre-FID construction contractors meeting the requirements set forth in Exhibit 5.

10.2 Post-FID Tenant’s Insurance. Prior to FID, the Tenant and the Landlord will cooperate in good faith to develop and agree to the levels and insurance coverages applicable from and after FID that are appropriate for an infrastructure facility such as the Facility that is: (a) under full construction, including insurance policies to be obtained by the Tenant’s construction contractors; and (b) appropriate once the Facility is operational, and in each case based upon input from a nationally recognized insurance advisor in the LNG industry jointly appointed by the Parties at the Tenant’s expense; provided that such insurance coverages are no less comprehensive than the insurance coverages recommended by the insurance advisor to the Financing Parties.

10.3 Insurance Providers. All insurance required to be carried by the Tenant under this Ground Lease shall be issued by insurance companies rated A-VII or better by A.M. Best, and reasonably acceptable to the Landlord. Each insurance policy carried by the Tenant in accordance with this Ground Lease shall include a waiver of the insurer’s rights of subrogation to the extent necessary to give effect to the release and shall name the Landlord as an additional named insured. The foregoing waiver shall be effective whether or not a waiving party shall obtain and maintain the insurance which such waiving party is required to obtain and maintain pursuant to this Ground Lease.

10.4 Landlord’s Insurance. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Site and/or any activities of the Landlord with respect to the Site in its reasonable business discretion. The Landlord may elect to be self-insured.

11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. During the term of this Ground Lease, the Landlord shall not create or permit to be created or to remain in connection with the Site, the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of the Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Site or upon the Landlord’s interest in the Site or upon the Tenant’s interest in its leasehold of the Site, in accordance with Section 11.2.

11.2 Discharge of Liens.

(a) If, during the term of this Ground Lease, any mechanics’, laborers’, or materialmen’s lien shall be filed against the Site or any part thereof in connection with the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit,

 

16


bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

(b) If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such Lien by deposit or by bonding proceedings. Any amount so paid by the non-responsible Party and all costs and expenses incurred by the non-responsible Party in connection therewith, including reasonable attorneys’ fees together with interest thereon at one percent (1%) per annum above the Wall Street Journal Prime Rate of interest published from time to time in the Wall Street Journal, from the respective dates of the non-responsible Party’s making of the payment or incurring of the cost and expense, shall constitute either additional Rent payable by the Tenant under this Ground Lease or an offset against Rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for (or offset against Rent) the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Site, including any taxes owed by the Landlord and other liabilities, obligations and/or debts owed to laborers, vendors, materialmen, and other service providers; provided, that the Landlord shall be in default of such obligations and the Tenant shall first provide reasonable prior notice to the Landlord of the Tenant’s intention to satisfy such obligations.

12. Entry on Premises by Landlord, Etc.

The Landlord and its representatives shall have no right to enter the Site, except: (1) as specifically authorized from time to time in advance in writing by the Tenant, or (2) in the event of an emergency, caused by casualty, natural disaster, or accident; provided the Landlord shall use reasonably practicable efforts to provide notice to the Tenant prior to entering the Site in the event of such emergency. If the Landlord, outside of an emergency as set forth in the preceding sentence, desires to inspect the Site, the Landlord shall provide the Tenant a written notice no less than five (5) Business Days prior to the date of such proposed entry. The Tenant may deny entry onto the Site if the Tenant reasonably believes that entry onto the Site by the Landlord and its representative poses a risk to (a) the health and/or safety of the Tenant’s or its contractor’s employees or personnel or to the Landlord or its representative or (b) the security, operation and/or maintenance of the Improvements. If and when entry onto the Site is granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of the Tenant. Such entry on the Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions

 

17


such that access to certain sections of the Site will be restricted. In no event shall any limitation or notice provision of this Section 12 prevent or impede entry onto the Site by the Landlord, any Affiliate or any Governmental Authority due to the emergency and necessary exercise of any valid police power under Applicable Laws; provided, that the Landlord shall use reasonable best efforts to preclude any interference with the Facility, and shall provide reasonable prior notice to the Tenant thereof unless such entry is necessary to prevent or respond to any imminent threat to life or damage to property.

13. Destruction by Fire or Other Casualty.

If any Improvements erected on the Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the willful misconduct of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Improvements. In the event that the Tenant so decides not to restore or reconstruct the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove any ruins or rubble remaining on the Site at the Tenant’s sole cost and expense.

14. Assignment; Subleasing.

14.1 Restrictions on Landlord. The Landlord shall not assign this Ground Lease or sell the Site, in whole or in part, (including by transfer of control or otherwise) without the prior written consent of the Tenant, which consent shall not be unreasonably withheld, conditioned, or delayed; provided, however, it shall not be unreasonable for the Tenant to withhold consent if (a) the Landlord requests to assign this Ground Lease or sell the Site, in whole or in part, to any Person, or any Affiliate of such Person, that is a direct or indirect competitor of the Tenant or any of its Affiliates, or (b) the Landlord requests to assign this Ground Lease or sell the Site, in whole or in part, to any Person that does not have substantially similar jurisdiction, authority, rights, and privileges as the Landlord as a political subdivision of the State of Louisiana. The Landlord covenants, represents and warrants as a condition of this Ground Lease as of the Ground Lease Commencement Date that the Landlord has no present intention to assign this Ground Lease or sell the Site, in whole or in part, during the Term.

14.2 Restrictions on Tenant. Subject to the provisions of Section 23, the Tenant shall not assign this Ground Lease, in whole or in part, without the prior written consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least thirty (30) days prior written notice of any proposed assignment and any other information that the Landlord may reasonably request; provided the Tenant is in possession of, or Tenant can reasonably acquire, such information, together with a copy of the proposed assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing, including to a Leasehold Lender, (ii) to a Leasehold Lender or any purchaser upon a foreclosure of a Leasehold Mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a Leasehold Mortgage, (iii) to any Affiliate or

 

18


member of the Tenant, (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, or (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder. The Tenant shall not sublease all or any portion of the Site without the prior written consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned.

15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of fifteen (15) days after written notice thereof from the Landlord to the Tenant.

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15.1(a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Site or discharge from the Site shall not constitute an Event of Default.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default, the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the Tenant shall be liable for such reasonable damages unless such Event of Default is reasonably remedied in a timely manner and all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default, together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and payable, and all costs and expenses reasonably incurred by or on behalf of the Landlord as a result of the Event of Default, including reasonable attorneys’ fees, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective and is not valid if the Landlord does not give prior written notice to the Tenant pursuant to Section 15.1.

 

19


(b) Landlord’s Remedies; Right to Cure Tenant’s Event of Default. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default that is not fully cured under Section 15.2(a), in addition to all other remedies available to the Landlord, the Landlord may terminate this Ground Lease by written notice to the Tenant. Upon the occurrence of an Event of Default of the Tenant which is not cured or which Tenant has not commenced to cure within sixty (60) days as provided in Section 15.2(a), then, subject to the prior written consent of any Leasehold Lender under Section 23, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others to cure the Event of Default. The Tenant shall be responsible for all costs, including attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord.

15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, following any Removal Period, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Site to the Landlord, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Site and may have, hold, and enjoy the Site; and (ii) all obligations of the Tenant hereunder for additional Rent or any portion thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. In the event of any termination, the Landlord shall be under a duty to seek a successor tenant. If the Landlord obtains a successor tenant during what would have been the remainder of the Term or any Removal Period, the Tenant shall receive a credit for rentals collected from said successor tenant for the remaining Term. If no successor tenant is obtained, the Tenant shall be liable for Rent obligations otherwise provided for in this Ground Lease.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

 

20


16. Events of Default of the Landlord.

16.1 Landlord Event of Default; Right to Cure. If default shall be made by the Landlord in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, and such default shall continue for a period of sixty (60) days after written notice thereof from the Tenant to the Landlord specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Landlord fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Landlord within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence), a “Landlord Event of Default” shall be deemed to have occurred hereunder.

16.2 Tenant’s Remedies; Cure. In the event of a Landlord Event of Default, in addition to all other remedies available to the Tenant, the Tenant may terminate this Ground Lease by written notice to the Landlord. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof, and shall be immediately payable to the Tenant. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default.

16.3 Tenant’s Right to Cure Landlord Event of Default. Upon the occurrence of a Landlord Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others, purchasing the required goods or services and procuring necessary insurance. The Landlord shall be responsible for all costs including attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

17. Mutual Obligations.

17.1 Late Charges; Interest. If any Rent or any other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of ten (10) days after receipt of written notice, such sum shall bear a late charge equal to one percent (1.0%) of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

 

21


17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise (excluding, however, specific performance against the Tenant) and the exercise or beginning of the exercise by the Parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by facsimile or United States registered or certified mail, return receipt and signature requested, postage prepaid, to the Parties at the following numbers and addresses:

 

  To the Tenant:        

Plaquemines Land Ventures, LLC

1001 19th St North

Suite 1500

Arlington, VA 22209

Attention: [***]

Facsimile: [***]

Email: [***]

  To the Landlord:     

Plaquemines Port, Harbor and Terminal

District 8056 Highway 23, Third Floor

Belle Chasse, LA 70037

Attn: [***]

Telephone: [***]

Facsimile: [***]

Email: [***]

 

22


  With a copy to:        

Plaquemines Port, Harbor and Terminal

District 8056 Highway 23, Third Floor

Belle Chasse, LA 70037

               

Attn: [***]

Telephone: [***]

Facsimile: [***]

Email: [***]

  With a copy to:     

Dwyer, Cambre, and Suffern, L.L.C.

3000 West Esplanade Ave., Ste. 200

Metairie, LA 70002

Attention: [***]

Telephone: [***]

Facsimile: [***]

Email: [***]

or to such other numbers or addresses as any of above designated recipients may from time to time designate by written notice to the other designated recipients hereto at least fifteen (15) days in advance of an effective date stated therein.

18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mail, return receipt and signature requested, postage prepaid.

19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable enjoyment of the Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Site during the Term and any Removal Period without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord. This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow industrial use of the remainder of their property adjacent to the Site.

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that: (i) it is the sole owner of good, marketable, fee simple title to all of the Site; (ii) the Site is subject to no Liens, privileges, encumbrances, defects in title, servitudes, easements, restrictions, dedications, leases, mineral leases, reservations or other exceptions to title, other than those existing on the Ground Lease Commencement Date; (iii) during the term hereof it shall not encumber the Site; (iv) it is authorized to make this Ground Lease for the term hereof; (v) the provisions of this Ground Lease do not and will not conflict with or violate any of the provisions of existing agreements between the Landlord and any third party; and (vi) the Landlord will deliver the Site free of all tenants and occupants and claims thereto.

 

23


20. Eminent Domain.

20.1 Complete Condemnation. If, during the term hereof, the whole of the Site shall be taken under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking) by any public or private authority, then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided that the Tenant shall share in the condemnation award as provided herein. The Tenant may continue to occupy the Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Site from and after the date of such taking.

20.2 Partial Condemnation. If, during the term hereof, any public or private authority shall, under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking), makes a taking resulting in the reduction of the surface area of the Site by fifteen percent (15%) or more, or of fifteen percent (15%) or more of the value of the Improvements or the Landlord’s Improvements, or resulting in material interference to the Improvements or the Tenant’s ability to use in a commercially reasonable manner the remainder of the Site, the Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of the exercise of its election within one-hundred twenty (120) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2, the term hereof shall cease and terminate as of the last day of the calendar month in which such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant, and the Tenant shall share in the condemnation award as provided herein.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the term hereof shall continue in full force and effect, and the monthly Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete taking pursuant to Section 20.1, the Tenant will be entitled to receive the portion of the condemnation award (or settlement) attributable to (i) the value of the Improvements and Landlord’s Improvements, and fixtures and other property located on the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, plus (iii) other compensation or benefits paid as a consequence of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking (if any such compensation or benefits are paid by the applicable taking authority) and the Landlord shall be entitled to recover that portion of the condemnation award (or settlement) fairly attributable to the value of the land taken. In the event the Tenant’s Property or the Improvements are not taken, the Tenant shall not be entitled to any portion of the award, and in the event no Landlord’s property is taken, the Landlord shall not be entitled to any portion of

 

24


the award. In the event of a partial taking of the Improvements and/or the Tenant’s Property the entire award or settlement shall be paid to the Tenant. In the event of a partial taking of the Site, the Tenant will be entitled to receive the portion of the award attributable to (i) the value of the portion of the Improvements and the Tenant’s Property located in the portion of the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, and the Tenant will promptly restore the remaining portion of the Improvements or the Site to the extent of the award payable to the Tenant. Nothing contained herein shall prohibit the Tenant’s claiming relocation damages or damages for lost profits or loss of leasehold advantage against the taking authority in any appropriate proceeding.

21. Temporary Taking or Other Deprivation.

If, during the term hereof, (i) less than all of the Landlord’s title to all or any portion of the Site is taken for temporary use or occupancy, or (ii) any public or private authority takes any action not resulting in a taking of all or any portion of the Site but resulting in a right to compensation therefor, such as changing of the grade of any street upon which the Site abuts, then, except as otherwise provided in Section 20, the Tenant shall be entitled to make claim for, recover, and retain all awards, whether pursuant to judgment, agreement, or otherwise, recoverable in connection therewith.

22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure; provided that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section 23 shall govern and control.

23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage, or any agent or trustee therefor, that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant. The term “Leasehold Mortgage” shall mean, at any point in

 

25


time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Site and this Ground Lease. It is acknowledged and agreed that, during the Term, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the Term, the Tenant shall provide the Landlord with written notice of the identity, contact information and address for each Leasehold Lender (or the agent authorized to act on behalf of the Leasehold Lender), such notice to be provided to the Landlord by the Tenant promptly after the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

23.2 Right to Perform for Tenant; Right to Cure.

(a) In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and the Landlord shall accept such performance by Leasehold Lender with the same force and effect as if furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing. Should Leasehold Lender fail to exercise its right to cure as provided above, the Landlord may terminate this Ground Lease by written notice to the Leasehold Lender.

(b) If any default in the performance of an obligation of the Tenant under this Ground Lease is not susceptible to being cured by Leasehold Lender, the Landlord shall have no right to terminate this Ground Lease with respect to such default and such default shall be deemed waived for the benefit of Leasehold Lender only; provided that:

(i) Leasehold Lender shall have commenced to cure (i) any other non- payment default of the Tenant that is susceptible to being cured by Leasehold Lender and (ii) any default in the payment of any portion of Rent, in each case, within the time periods prescribed under Section 23.2(a);

(ii) Leasehold Lender (or its designee) shall have commenced to acquire the Tenant’s interest in this Ground Lease and the Site or to commence foreclosure or other appropriate proceedings under the Leasehold Mortgage within the time periods prescribed under Section 23.2(a);

 

26


(iii) if Leasehold Lender (or its designee) shall acquire the Tenant’s interest in this Ground Lease and/or the Site, Leasehold Lender (or its designee) shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition; and

(iv) if any third party shall, by foreclosure or dation en paiement under the Leasehold Mortgage or by assignment or other transfer from Leasehold Lender, acquire the Tenant’s interest in and to the Site under this Ground Lease, such third party shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by a third party with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition.

However, if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then notwithstanding any provision in this Section 23 to the contrary, the Landlord may exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’s prior written consent, and any such action taken without Leasehold Lender’s consent shall not be binding on the Tenant or the Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.4 Delivery of Notices. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been delivered to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in writing to the Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

 

27


23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’s interests in the Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including the acquisition of the Tenant’s interest in this Ground Lease and the Site created thereby in a transaction described in this Section 23 or the taking of possession of the Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender; provided that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Site.

23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2, the purchaser at any sale of this Ground Lease and the interests in and to the Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Site thereby created under any instrument of assignment or transfer in lieu of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Site thereby created.

23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, or substantially all of the Site. Rent shall continue to be due and payable as set forth in this Ground Lease.

 

28


23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent domain proceeding of all, substantially all, or any part of the Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Site created by this Ground Lease and the value of the leasehold improvements located on the Site, up to an amount equaling the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Tenant’s interest in, under and to this Ground Lease; provided that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under Applicable Laws to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this Ground Lease. In the event of a taking of a portion of the Site, the Rent shall be reduced pro rata based upon the portion of the Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease.

23.9 New Direct Lease.

(a) If this Ground Lease is canceled or terminated for any reason (except in connection with a Bankruptcy Proceeding, for which the provisions of Section 23.10 are hereby agreed upon by the Landlord and the Tenant), and provided that Leasehold Lender has (i) commenced to cure and continues diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, and (ii) cured any payment default in respect of any portion of Rent, the Landlord hereby agrees that the Landlord shall, upon Leasehold Lender’s written election within one hundred twenty (120) days of such cancellation or termination, promptly enter in a new, direct lease with Leasehold Lender (or its nominee or any other party which Leasehold Lender may designate, including the Tenant) with respect to the Site on the same terms and conditions as this Ground Lease (a “New Lease”), it being the intention of the parties to preserve this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Said New Lease shall be superior to all rights, liens and interests intervening between the date of this Ground Lease and the granting of the New Lease and shall be free of any and all rights of the Tenant under this Ground Lease.

(b) The Tenant and the Landlord acknowledge and agree that Leasehold Lender shall have the right to encumber such direct New Lease and the estate created thereby with a deed of trust or a mortgage (as the case may be) on the same terms and with the same lien priority as the Leasehold Mortgage, it being the intention of the parties to preserve the priority of the Leasehold Mortgage, this Ground Lease and the interests in and to the Site created by this Ground

 

29


Lease for the benefit of Leasehold Lender without interruption. If this Ground Lease is rejected, cancelled or terminated for any reason and Leasehold Lender, its nominee or a designee of Leasehold Lender enters into a direct lease with the Landlord with respect to the Site, the Landlord hereby agrees that it will execute such documents as Leasehold Lender may require in order to ensure that the new direct lease provides for customary leasehold mortgagee protections, including protections similar to those contained herein.

23.10 Bankruptcy. In the event of a proceeding under the United States Bankruptcy Code (Title 11 U.S.C.) as now or hereafter in effect (a “Bankruptcy Proceeding”):

(a) If this Ground Lease is rejected in connection with a Bankruptcy Proceeding by the Tenant or a trustee in bankruptcy (or other party to such proceeding) for the Tenant, such rejection shall be deemed an assignment by the Tenant to the Leasehold Lender of the Tenant’s Property and all of the Tenant’s interest under this Ground Lease, and this Ground Lease shall not terminate and the Leasehold Lender shall have all rights and obligations of the Tenant as if such Bankruptcy Proceeding had not occurred, unless Leasehold Lender shall reject such deemed assignment by notice in writing to the Landlord within thirty (30) days following rejection of this Ground Lease by the Tenant or the Tenant’s trustee in bankruptcy. If any court of competent jurisdiction shall determine that this Ground Lease shall have been terminated notwithstanding the terms of the preceding sentence as a result of rejection by the Tenant or the trustee in connection with any such proceeding, the rights of Leasehold Lender to a New Lease from the Landlord pursuant to Section 23.9 hereof shall not be affected thereby.

(b) In the event of a Bankruptcy Proceeding against the Landlord:

(i) If the bankruptcy trustee, the Landlord (as debtor-in-possession) or any party to such Bankruptcy Proceeding seeks to reject this Ground Lease pursuant to United States Bankruptcy Code §365(h)(1), the Tenant shall not have the right to treat this Ground Lease as terminated except with the prior written consent of Leasehold Lender and the right to treat this Ground Lease as terminated in such event shall be deemed assigned to Leasehold Lender, whether or not specifically set forth in the Leasehold Mortgage, so that the concurrence in writing of the Tenant and the Leasehold Lender shall be required as a condition to treating this Ground Lease as terminated in connection with such Bankruptcy Proceeding.

(ii) Unless this Ground Lease is treated as terminated in accordance with Section 23.10(b)(i), then this Ground Lease shall continue in effect upon all the terms and conditions set forth herein, including Rent, but excluding requirements that are not then applicable or pertinent to the remainder of the Term. Thereafter, the Tenant or its successors and assigns shall be entitled to any offsets against Rent payable hereunder for any damages arising from such bankruptcy, to the extent the Tenant’s operation of business has been materially interfered with, and any such offset properly made shall not be deemed a default under this Ground Lease. The lien of the Leasehold Mortgage shall extend to the continuing possessory rights of the Tenant following such rejection with the same priority as it would have enjoyed had such rejection not taken place.

 

30


23.11 Estoppel Certificates; Non-Disturbance Agreements.

(a) Within twenty (20) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel”) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under this Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant hereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy hereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that each of this Ground Lease and the Non-Disturbance Agreement (as defined in Section 23.11(c)), true, correct copies of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, have not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Term is scheduled to expire, (vii) as to the Landlord’s power and authority to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or Applicable Laws or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease and any Non-Disturbance Agreement, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which the Landlord is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the Landlord Estoppel, the present lessor under this Ground Lease and owns good and indefeasible title to the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (xix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

 

31


(b) Within twenty (20) days following Leasehold Lender’s or the Landlord’s written request, the Tenant shall provide Leasehold Lender with an estoppel certificate (the “Tenant Estoppel”) which shall certify to such requesting Leasehold Lender (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non- compliance by the Landlord of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Landlord of any other conditions required under this Ground Lease, (iii) as to any existing default of the Landlord under this Ground Lease, or alternatively that the Landlord is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Landlord hereunder, and as to any existing event or condition in existence as of the date of the Tenant Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Tenant to terminate, accelerate, or modify this Ground Lease or exercise any other remedy hereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Tenant, (v) that this Ground Lease, a true and correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Term is scheduled to expire, (vii) as to the Tenant’s power and authority to execute the Tenant Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Tenant asserting that (A) this Ground Lease violates any agreement or Applicable Laws or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Tenant from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties, or other sums, whether or not constituting rent, due and owing as of the date of the Tenant Estoppel and as to any rent that the Tenant has prepaid under this Ground Lease, (xii) that, except for this Ground Lease, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which the Tenant is a party (other than those set forth on a schedule to the Tenant Estoppel (provided that Landlord shall only be bound by written agreements signed by Landlord as provided by Section 24.6 herein)), (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Tenant Estoppel, (xiv) that the Tenant is, as of the date of the Tenant Estoppel, the present lessee under this Ground Lease and holds a valid leasehold interest in the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Tenant has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Tenant’s interest in the Site, other than those set forth on a schedule to the Tenant Estoppel, (xvi) that there exist no options, rights of first

 

32


refusal, or other similar rights or agreements to which the Tenant is a party or by which the Tenant is otherwise bound affecting the Tenant’s interest in and to the Site, (xvii) that the Tenant has not commenced any action or sent any notice to the Landlord for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Tenant is not, as of the date of the Tenant Estoppel, entitled to terminate, cancel, modify, or surrender this Ground Lease, and (xviii) as to such other matters related to this Ground Lease as such Leasehold Lender may reasonably determine from time to time.

(c) Within twenty (20) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall enter into a non-disturbance agreement with Leasehold Lender or its designee, in the form attached hereto as Exhibit 4 (a “Non-Disturbance Agreement”).

23.12 No Merger. There shall be no merger of this Ground Lease or any interest in this Ground Lease or of the interests in and to the Site created thereby with the fee estate in the Site, by reason of the fact that this Ground Lease or such interest therein, may be directly or indirectly held by or for the account of any person who shall hold any interest in the fee estate in the Site, nor shall there be such a merger by reason of the fact that all or any part of the interests in and to the Site created by this Ground Lease may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any interest in the fee estate in the Site or any interest of the Landlord under this Ground Lease.

23.13 Landlord’s Recognition of Tenant. The Landlord hereby recognizes the Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that the Tenant acquired its interest in this Ground Lease and in and to the Site in accordance with the terms of this Ground Lease.

23.14 Agreement to Amend. The Landlord recognizes the importance of the Tenant’s ability to obtain Leasehold Mortgages, and that the provisions of this Ground Lease may be subject to the approval of a Leasehold Lender. If any Leasehold Lender should require, as a condition to such financing, any reasonable modifications of this Ground Lease, whether for purposes of clarifying the provisions of this Ground Lease or to include provisions then customary for leasehold financing transactions, the Landlord agrees to execute the appropriate amendments to this Ground Lease; provided, however, that no such modification shall, to the detriment of the Landlord, impair any of the Landlord’s rights, as reasonably determined by the Landlord or increase any of the Landlord’s obligations, as reasonably determined by the Landlord, under this Ground Lease.

23.15 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

23.16 Subordination of Landlord’s Lien. The Landlord hereby subordinates any lien or privilege it may have on any movables found from time to time in or upon the Site, including Landlord’s privileges pursuant to La. Civil Code articles 2707, et seq., to any Leasehold Lender’s rights under this Section 23 and the lien of any Leasehold Mortgage.

 

33


24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

24.2 Successors. The covenants, agreements, terms, provisions, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties hereto.

24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

24.6 No Oral Change or Termination. This Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties hereto with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

 

34


24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

24.9 Dispute Resolution.

(a) If a dispute between the Parties arises out of, under or in connection with this Ground Lease, including its interpretation, performance, enforcement, termination, validity or breach, any Party shall provide notice of such dispute to the other Party. Within fifteen (15) days after the receipt of such notice, or such longer time as mutually agreed to by the Parties, the Parties shall meet, and the meeting shall be attended by representatives of the senior management of the Parties with decision-making authority regarding such dispute, to attempt in good faith to negotiate a resolution to such dispute.

(b) If, after the management settlement conference set forth in Section 24.9(a), the Parties to the dispute have not succeeded in negotiating a resolution of the dispute, then either Party to the dispute may refer the matter to litigation. Completion of the management settlement conference set out in Section 24.9(a) shall be a condition precedent to initiating such litigation; provided, however, the failure of a Party to participate in the management settlement conference set forth in Section 24.9(a) shall not prevent the other Party from referring a dispute to litigation.

(c) In case of any litigation between the Parties hereto regarding the subject matter hereof, the losing Party shall pay all reasonable costs and expenses (including reasonable attorneys’ fees) of the prevailing Party. The venue of any litigation shall be solely in Plaquemines Parish, Louisiana.

24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

24.11 Authority. The Landlord and the Tenant each represents and warrants that it has the authority to enter into this Ground Lease, that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date, (a) the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 2, evidencing its authority to execute and perform under this Ground Lease and (b) the Landlord shall deliver to the Tenant a resolution in the form attached hereto as Exhibit 3, evidencing its authority to execute and perform under this Ground Lease.

23.12 No Waiver. Neither acceptance of Rent by the Landlord nor failure by the Landlord to complain of any action, non-action or default of the Tenant, whether singular or repetitive, shall constitute a waiver of any of the Landlord’s rights hereunder. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Site and no agreement to accept a surrender of the Site shall be valid unless it is in writing and signed by the Landlord.

 

35


24.13 Limited Recourse. The Landlord agrees that the sole recourse of the Landlord for any damages or liabilities due by the Tenant hereunder shall be limited to the assets of the Tenant, without recourse individually or collectively to the members or the Affiliates of the Tenant, the Leasehold Lenders or their respective directors, officers, agents, members, shareholders, managers, partners, employees or representatives.

24.14 Further Assurances. In connection with this Ground Lease and the transactions contemplated hereby, each Party shall execute and deliver any additional documents and instruments and perform any additional acts that may be necessary or appropriate on a commercially reasonable basis to effectuate and perform the provisions of this Ground Lease and those transactions, including in connection with the requests of any Financing Parties or Leasehold Lender.

24.15 Brokers and/or Real Estate Agents. The Landlord and the Tenant each represent to the other party that they have dealt with no brokers in connection with the negotiation, execution and/or delivery of this Ground Lease, and that no party is entitled to any broker’s commission, finder’s fee or similar payment with respect to this Ground Lease arising from the representing party’s actions. If any other person shall assert a claim to a finder’s fee, brokerage commission or other compensation on account of alleged employment as finder or broker in connection with this transaction, the party against whom the purported finder or broker is claiming shall indemnify, defend and hold the other party harmless from and against any such claim and any and all costs, expenses and liabilities incurred in connection with such claim or any action or proceeding brought thereon, including reasonable attorneys’ fees and court costs in defending such claim.

24.16 Legal Relationships; Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. There is no third party beneficiary of this Ground Lease, except as provided in Section 23.15 and any rights of a Leasehold Lender as provided herein. This Ground Lease is the product of the Parties joint negotiation and equal drafting thereof. The language of this Ground Lease shall be construed as a whole according to its fair meaning and not construed strictly for or against any of the Parties pursuant to any statue, case law or rule of interpretation or construction to the contrary.

24.17 Memorandum of Lease. The Parties hereto agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’s interest hereunder; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease. The Parties further agree to execute, and Tenant agrees to cause to be properly recorded, a memorandum of termination of this Ground Lease following any early termination hereof.

[Remainder of page left intentionally blank; signatures on following pages]

 

36


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

/s/ Karolyn Sherman

           LANDLORD:
WITNESS      PLAQUEMINES PORT HARBOR & TERMINAL DISTRICT

/s/ Erica Braun

     By: /s/ Maynard J. Sanders     
WITNESS      Name: Maynard J. Sanders
     Title:  Executive Director

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Plaquemines and State of Louisiana, personally came and appeared Maynard Sanders, who, after being sworn by me, did execute this agreement on the 14th day of January, 2022 at Belle Chasse, State of Louisiana.

    /s/ J. Kendal Rathburn    

NOTARY PUBLIC

 

/s/ John Thompson

            TENANT:
WITNESS John Thompson       PLAQUEMINES LAND VENTURES, LLC

/s/ Sandra Y Snyder

      By: /s/ Keith Larson     
WITNESS Sandra Y Snyder       Name: Keith Larson
      Title: Secretary

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 19th day of January, 2022 at Arlington, State of Virginia.

    /s/ Annette B. Thrasher    

NOTARY PUBLIC

 

1


LIST OF EXHIBITS

Exhibit 1-A Legal Description of Site

Exhibit 1-B Site Survey

Exhibit 2 Tenant’s Resolution

Exhibit 3 Landlord’s Resolution

Exhibit 4 Form of Non-Disturbance Agreement

Exhibit 5 Contractor Insurance Requirements

 

1


EXHIBIT 1-A

LEGAL DESCRIPTION OF THE SITE

LEGAL DESCRIPTION: ±80.142 ACRE SURFACE LEASE (DR-4A)

80.142 ACRES, MORE OF LESS, OF LAND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS:

A TRACT OF LAND CONSISTING OF A PORTION OF TRACT DR-4A, SITUATED IN SECTION 1 & 15, TOWNSHIP 17 SOUTH, RANGE 25 EAST AND IN SECTIONS 21 & 22, TOWNSHIP 17 SOUTH, RANGE 26 EAST, PLAQUEMINES PARISH, LOUISIANA, HAVING AN AREA OF 128.809 ACRES MORE OF LESS, AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS:

BEGINNING AT A POINT HAVING LOUISIANA STATE PLANE COORDINATES OF EASTING (X) = 3,743,117.90’ AND NORTHING (Y) = 403,825.10’, ALSO BEING THE POINT OF BEGINNING LABELED P.O.C. / P.O.B. 2;

THENCE S 24°36’16” W A DISTANCE OF 3,795.83 FEET TO A POINT;

THENCE N 79°36’21” W A DISTANCE OF 25.17 FEET TO A POINT;

THENCE S 58°01’57” W A DISTANCE OF 135.52 FEET TO A POINT;

THENCE N 77°09’42” W A DISTANCE OF 1,680.35 FEET TO A POINT;

THENCE N 32°37’59” E A DISTANCE OF 4,001.34 FEET TO A POINT;

THENCE S 66°00’41” E A DISTANCE OF 10.99 FEET TO A FOUR (4) INCH CONCRETE

MONUMENT (DISTURBED);

THENCE WITH A CURVE TURNING TO THE LEFT WITH AN ARC LENGTH OF 753.03’, WITH A RADIUS OF 2,329.55’, WITH A CHORD BEARING OF

S 75°59’56” E, WITH A CHORD LENGTH OF 749.75 FEET TO A FOUND FOUR (4) INCH CONCRETE MONUMENT (DISTURBED);

THENCE S 85°12’37” E A DISTANCE OF 464.81 FEET TO THE POINT OF BEGINNING LABELED P.O.C. /P.O.B. 2.

 

1


LESS AND EXCEPT, FROM SAID 128.809 ACRE TRACT, 48.667 ACRES, MORE OF LESS, OF LAND BEING A PORTION OF A 80.000 ACRE TRACT DESCRIBED AS A LAYDOWN SURFACE LEASE, IN A DEED DATED JULY 19, 2021, RECORDED IN BOOK 1440, PAGE 542, DEED RECORDS OF PLAQUEMINES PARISH, LOUISIANA (SUCH 80-ACRE TRACT DESCRIBED BELOW).

LEGAL DESCRIPTION: ±410.043 ACRE SURFACE LEASE (PORTION OF TRACT F-1)

410.043 ACRES, MORE OF LESS, OF LAND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS:

A TRACT OF LAND CONSISTING OF A PORTION OF TRACT F-1, SITUATED IN SECTION 15, TOWNSHIP 17 SOUTH, RANGE 25 EAST AND IN SECTIONS 20 & 21, TOWNSHIP 17 SOUTH, RANGE 26 EAST, PLAQUEMINES PARISH, LOUISIANA, HAVING AN AREA OF 441.376 ACRES MORE OF LESS, AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS:

BEGINNING AT A POINT HAVING LOUISIANA STATE PLANE COORDINATES OF EASTING (X) = 3,743,117.90’ AND NORTHING (Y) = 403,825.10’, ALSO BEING THE POINT OF BEGINNING LABELED P.O.C. / P.O.B. 2;

THENCE S 85°12’37” E A DISTANCE OF 3,567.47 FEET TO A FOUND FOUR (4) INCH CONCRETE MONUMENT (DISTURBED);

THENCE WITH A CURVE TURNING TO THE RIGHT WITH AN ARC LENGTH OF 710.72’, WITH A RADIUS OF 18,260.82’, WITH A CHORD BEARING OF

S 84°09’26” E, WITH A CHORD LENGTH OF 710.68 FEET TO A FOUND FOUR (4) INCH CONCRETE MONUMENT (DISTURBED);

THENCE S 83°02’32” E A DISTANCE OF 720.94 FEET TO A FOUND 1/2” IRON PIPE; THENCE S 23°36’56” W A DISTANCE OF 734.62 FEET TO A FOUND 3/4” IRON PIPE; THENCE S 23°36’56” W A DISTANCE OF 400.17 FEET TO A FOUND 3/4” IRON PIPE; THENCE S 23°36’56” W A DISTANCE OF 423.11 FEET TO A FOUND 3/4” IRON PIPE (BENT);

 

2


THENCE S 23°36’56” W A DISTANCE OF 2,694.44 FEET TO A POINT; THENCE N 67°57’32” W A DISTANCE OF 59.13 FEET TO A POINT; THENCE N 79°36’21” W A DISTANCE OF 4,879.82 FEET TO A POINT;

THENCE N 24°36’16” E A DISTANCE OF 3,795.83 FEET TO THE POINT OF BEGINNING LABELED P.O.C. / P.O.B. 2.

LESS AND EXCEPT, FROM SAID 441.376 ACRE TRACT, 31.333 ACRES, MORE OF LESS, OF LAND BEING A PORTION OF A 80.000 ACRE TRACT DESCRIBED AS A LAYDOWN SURFACE LEASE, IN A DEED DATED JULY 19, 2021, RECORDED IN BOOK 1440, PAGE 542, DEED RECORDS OF PLAQUEMINES PARISH, LOUISIANA (SUCH 80-ACRE TRACT DESCRIBED BELOW).

LEGAL DESCRIPTION: ±27.444 ACRE SURFACE LEASE (PORTION OF TRACT G)

A TRACT OF LAND CONSISTING OF A PORTION OF TRACT G, SITUATED IN IN SECTIONS 20 & 21, TOWNSHIP 17 SOUTH, RANGE 26 EAST, PLAQUEMINES PARISH, LOUISIANA, HAVING AN AREA OF 27.444 ACRES MORE OF LESS, AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS:

BEGINNING AT A FOUND 2” IRON PIPE, HAVING LOUISIANA STATE PLANE COORDINATES OF EASTING (X) = 3,745,213.28’ AND NORTHING (Y) = 403,899.70’, ALSO BEING THE POINT OF BEGINNING LABELED P.O.C. / P.O.B. 1;

THENCE S 85°19’27” E A DISTANCE OF 649.53 FEET TO A FOUND 3/4” IRON PIPE; THENCE N 04°55’06” E A DISTANCE OF 128.08 FEET TO A FOUND 1/2” IRON ROD; THENCE N 04°55’06” E A DISTANCE OF 222.99 FEET TO A POINT ON THE SOUTHERLY BANK OF THE MISSISSIPPI RIVER;

THEN GO SOUTH EASTERLY ALONG THE SOUTHERLY BANK OF THE MISSISSIPPI RIVER, THE FOLLOWING COURSES & DISTANCES:

THENCE S 79°28’06” E A DISTANCE OF 77.00 FEET TO A POINT; THENCE S 80°09’10” E A DISTANCE OF 180.05 FEET TO A POINT;

THENCE S 81°05’54” E A DISTANCE OF 437.31 FEET TO A POINT;

 

3


THENCE S 80°38’03” E A DISTANCE OF 7.27 FEET TO A POINT;

THENCE DEPARTING THE SOUTHERLY BANK OF THE MISSISSIPPI RIVER S 07°46’53” W A DISTANCE OF 172.47 FEET TO A POINT;

THENCE S 07°46’53” W A DISTANCE OF 128.20 FEET TO A FOUND 3/4” IRON PIPE; THENCE WITH A CURVE TURNING TO THE RIGHT WITH AN ARC LENGTH OF 75.63’, WITH A RADIUS OF 5,704.65’, WITH A CHORD BEARING OF

S 83°02’25” E, WITH A CHORD LENGTH OF 75.63’, TO A POINT;

THENCE S 82°39’29” E A DISTANCE OF 374.38 FEET TO A FOUND 3/4” IRON PIPE;

THENCE N 07°47’03” E A DISTANCE OF 116.76 FEET TO A POINT;

THENCE N 07°47’03” E A DISTANCE OF 161.22 FEET TO A POINT ON THE SOUTHEAST BANK OF THE MISSISSIPPI RIVER;

THEN GO SOUTH EASTERLY ALONG THE SOUTHERLY BANK OF THE MISSISSIPPI RIVER, THE FOLLOWING COURSES & DISTANCES:

THENCE S 79°13’05” E A DISTANCE OF 599.67 FEET TO A POINT;

THENCE S 81°30’00” E A DISTANCE OF 313.95 FEET TO A POINT;

THENCE S 82°50’29” E A DISTANCE OF 266.57 FEET TO A POINT;

THENCE S 83°35’41” E A DISTANCE OF 146.06 FEET TO A POINT;

THENCE S 82°21’56” E A DISTANCE OF 84.04 FEET TO A POINT;

THENCE DEPARTING THE SOUTHERLY BANK OF THE MISSISSIPPI RIVER S 09°49’03” W A DISTANCE OF 139.18 FEET TO A POINT;

THENCE S 09°49’03” W A DISTANCE OF 104.61 FEET TO A POINT;

THENCE S 09°49’41” W A DISTANCE OF 187.60 FEET TO A POINT;

THENCE WITH A CURVE TURNING TO THE LEFT WITH AN ARC LENGTH OF 1,764.78’, WITH A RADIUS OF 22,771.47’, WITH A CHORD BEARING OF

 

4


N 82°59’05” W, WITH A CHORD LENGTH OF 1,764.34’, TO A POINT;

THENCE N 85°16’52” W A DISTANCE OF 1,403.26 FEET TO A POINT;

THENCE N 04°47’52” E A DISTANCE OF 210.53 FEET TO THE POINT OF BEGINNING LABELED P.O.C. / P.O.B. 1.

LEGAL DESCRIPTION: ±5.920 ACRE SURFACE LEASE (TRACT B-1)

A CERTAIN TRACT OF LAND CONSISTING OF TRACT B-1, SITUATED IN SECTION 21, TOWNSHIP 17 SOUTH, RANGE 26 EAST, PLAQUEMINES PARISH, LOUISIANA, HAVING AN AREA OF 5.920 ACRES MORE OF LESS, AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS:

BEGINNING AT A FOUND 2” IRON PIPE, HAVING LOUISIANA STATE PLANE COORDINATES OF EASTING (X)= 3,745,213.28’ AND NORTHING (Y) = 403,899.70’, ALSO BEING THE POINT OF BEGINNING LABELED P.O.C / P.O.B. 1;

THENCE N 04°47’52” E A DISTANCE OF 182.18 FEET TO A FOUND 1/2” IRON ROD;

THENCE N 04°47’52” E A DISTANCE OF 264.73 FEET TO A POINT ON THE SOUTHERLY BANK OF THE MISSISSIPPI RIVER;

THENCE GO SOUTH EASTERLY ALONG THE SOUTHERLY BANK OF THE MISSISSIPPI RIVER THE FOLLOWING COURSES & DISTANCES:

THENCE S 76°24’07” E A DISTANCE OF 420.91 FEET TO A POINT;

THENCE S 77°25’41” E A DISTANCE OF 156.62 FEET TO A POINT;

THENCE S 78°47’58” E A DISTANCE OF 79.62 FEET TO A POINT;

THENCE DEPARTING THE SOUTHERLY BANK OF THE MISSISSIPPI RIVER S 04°55’06” W A DISTANCE OF 222.99 FEET TO A FOUND 1/2” IRON ROD;

THENCE S 04°55’06” W A DISTANCE OF 128.08 FEET TO A FOUND 3/4” IRON PIPE;

 

5


THENCE N 85°19’27” W A DISTANCE OF 649.53 FEET TO THE POINT OF BEGINNING LABELED P.O.C. /P.O.B. 1.

LESS AND EXCEPT:

LEGAL DESCRIPTION: ±80.00 ACRE LAYDOWN SURFACE LEASE (TRACTS DR-4 AND F-1)

80.000 ACRE TRACT DESCRIBED AS A LAYDOWN SURFACE LEASE, IN A DEED DATED JULY 19, 2021, RECORDED IN BOOK 1440, PAGE 542, DEED RECORDS OF PLAQUEMINES PARISH, LOUISIANA, AND BEING FURTHER DESCRIBED AS FOLLOWS.

A CERTAIN TRACT OF LAND CONSISTING OF A PORTION OF TRACT DR-4A & PORTION OF TRACT F-1, SITUATED IN SECTION 1, TOWNSHIP 17 SOUTH, RANGE 25 EAST AND IN SECTIONS 21 & 22, TOWNSHIP 17 SOUTH, RANGE 26 EAST, PLAQUEMINES PARISH, LOUISIANA, HAVING AN AREA OF 80.000 ACRES MORE OF LESS, AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS:

COMMENCING AT A POINT HAVING COORDINATES OF EASTING (X) 3,741,917.19’ AND NORTHING (Y) 404,049.77’ LOUISIANA SOUTH ZONE, NAD83 (2011), ALSO BEING THE POINT OF BEGINNING OF THE HEREIN DESCRIBED PROPOSED LAYDOWN SURFACE LEASE.

THENCE S 66°00’41” E A DISTANCE OF 10.99 FEET TO A DISTURBED FOUR (4) INCH CONCRETE MONUMENT;

THENCE WITH A CURVE TURNING THE LEFT WITH AN ARC LENGTH OF 753.03 FEET, HAVING A RADIUS OF 2,329.55 FEET, WITH A CHORD BEARING OF S 75°59’56” E, WITH A CHORD LENGTH OF 749.75 FEET, TO A DISTURBED FOUR (4) INCH CONCRETE MONUMENT;

THENCE S 85°12’37” E A DISTANCE OF 976.71 FEET TO A POINT;

THENCE S 06°02’07” W A DISTANCE OF 1,658.52 FEET TO A POINT;

 

6


THENCE S 89°40’21” W A DISTANCE OF 993.01 FEET TO A POINT;

THENCE N 66°32’13” W A DISTANCE OF 1,513.68 FEET TO A POINT;

THENCE N 32°37’59” E A DISTANCE OF 1,567.12 FEET TO A POINT TO THE POINT OF BEGINNING;

 

7


EXHIBIT 1-B

BOUNDARY SURVEY OF SITE

[Omitted]


EXHIBIT 2

TENANT’S RESOLUTION

[Omitted]


EXHIBIT 3

LANDLORD’S RESOLUTION

[Omitted]


EXHIBIT 4

FORM OF NON-DISTURBANCE AGREEMENT

[Omitted]


EXHIBIT 5

CONTRACTOR INSURANCE REQUIREMENTS

[Omitted]

Exhibit 10.56

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

STATE OF LOUISIANA

PARISH OF CAMERON

AMENDED AND RESTATED GROUND LEASE AGREEMENT

(840 Acres)

This AMENDED AND RESTATED GROUND LEASE AGREEMENT (this “CLV Ground Lease”) is executed and effective as of September 19, 2023 (the “CLV Ground Lease Commencement Date”), by and between Cameron Land Ventures, LLC, a Delaware limited liability company (the “Tenant”) and J.A. Davis Properties, LLC, a Louisiana limited liability company (the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as a “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Cameron Parish, Louisiana, which comprises approximately eight hundred forty (840) acres, as further defined below;

WHEREAS, the Tenant wishes to lease land owned by the Landlord to support the Tenant’s business activities (or those of its successors and permitted assigns);

WHEREAS, the Property is subject to that certain ground lease agreement entered into by Landlord and Port Cameron, LLC dated December 28, 2014 as evidenced by that certain Memorandum of Lease recorded March 26, 2015 as File Number 335292 in the official records of Cameron Parish, Louisiana, as amended by Landlord and Port Cameron Phase 1, LLC (successor in interest to Port Cameron, LLC) on December 14, 2018, as evidenced by that certain Memorandum of Amendment to Ground Lease Agreement recorded January 2, 2019 as File Number 344601 in the official records of Cameron Parish, Louisiana, as assigned by Port Cameron Phase 1, LLC to Port Louisiana, Inc. on December 21, 2018, as evidenced by that certain Memorandum of Assignment and Agreement recorded January 22, 2019 as File Number 344686 in the official records of Cameron Parish, Louisiana (the “PL Ground Lease”);

WHEREAS, the Port Louisiana, Inc., Landlord and the Tenant entered into an Amendment and Assignment Agreement, effective as of September 19, 2023 (the “Assignment”) pursuant to which the Landlord consented to the assignment to the Tenant and this amendment and restatement of the PL Ground Lease;

WHEREAS, the Landlord and the Tenant have agreed to amend and restate the PL Ground Lease in its entirety on the terms and conditions set forth in this CLV Ground Lease to, among other things, release to the Landlord the Excluded Area (as defined below) leased under the PL Ground Lease (the “Excluded Area”); and

WHEREAS, in accordance with the above, the Tenant has executed this CLV Ground Lease and offers fair value to the Landlord as cause and consideration for this CLV Ground Lease.


NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this CLV Ground Lease, and the Parties herein covenant and agree as follows:

1. Definitions and Interpretation.

As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

Additional Rent” has the meaning set forth in Section 4.3.

Adjustment Period” has the meaning set forth in Section 4.1.

Affiliate” means, in respect of any Person, any other Person controlled by, controlling or under common control with such first Person. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of thirty percent (30%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.

Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Site.

Bankruptcy Proceeding” has the meaning set forth in Section 23.10.

Base Rent” has the meaning set forth in Section 4.1.

Bona Fide Offer” means a bona fide written offer to purchase all or any portion of the Site from a true, independent third party, who is not an Affiliate of the Landlord and who is otherwise making the offer in good faith and on an arms-length basis that the Landlord desires to accept.

Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in the State of New York are authorized or required by law to close.

Consumer Price Index” has the meaning set forth in Section 4.2.

Corps” has the meaning set forth in Section 8.3(a).

Corrective Measures” has the meaning set forth in Section 9.4(b).

CPI Adjustment” has the meaning set forth in Section 4.1.

 

2


CPI Disagreement Notice” has the meaning set forth in Section 4.2.

CPI Notice” has the meaning set forth in Section 4.2.

CPI Percentage Increase” has the meaning set forth in Section 4.2.

Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Law relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

Event of Default” has the meaning set forth in Section 15.1.

Excluded Area” means the real (immovable) property of approximately ten (10) acres depicted and described on the survey by Lonnie G. Harper & Associates, Inc., dated June 26, 2023, attached hereto as Exhibit 9.

Extended Term” has the meaning set forth in Section 3.2(a).

Facilities” means an equipment offloading area, construction laydown area, parking lot, administrative facility, facilities to provide access to other properties controlled by the Tenant or its Affiliates, berthing facilities, and for other uses in connection with the development, permitting, financing, construction, ownership, operation, and maintenance of a multi-purpose energy terminal facility and other Improvements (as hereinafter defined) in Cameron Parish, Louisiana, which may include natural gas facilities for the production, importation, regasification, storage, and export of liquefied natural gas, and such other ancillary and/or related uses that are permitted by Applicable Laws.

Facility Contractor” means any Person (other than the Tenant or its Affiliate) that is party to a Facility Contract.

Facility Contracts” means, collectively, the contracts entered into by the Tenant in connection with the design, engineering, construction, equipment procurement, testing, commissioning, operation and maintenance of the Facilities, the Site and/or the Improvements.

Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Facilities, the Improvements, the Site, or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders.

 

3


Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, droughts, floods, washouts, explosions, breakage or accident or necessity of repairs to machinery or equipment or lines of pipe; (ii) weather related events affecting an entire geographic region; (iii) acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, terrorism, discovery of burial grounds or human remains or legally protected artifacts, insurrections or wars; (iv) the failure or interruption of performance by the Tenant’s engineering, procurement and construction contractor or any subcontractors of such contractor to the extent caused by an event of Force Majeure under this Ground Lease; (v) the failure or interruption of performance by the Tenant’s suppliers by reason of such supplier’s valid declaration of an event that would constitute an event of force majeure under the Tenant’s contract with such supplier; and (vi) governmental actions such as necessity for compliance with any court order, law, statute, ordinance, regulation, or policy having the effect of law promulgated by a Governmental Authority having jurisdiction, or that restrict the Tenant’s ability to reasonably construct and/or operate the Facilities or the Improvements or any delay in issuance or effectiveness of any Governmental Approval that has been properly applied for by the Tenant that is required to construct and/or operate the Facilities or the Improvements.

Governmental Approval” means any authorization, waiver, consent, approval, license, environmental remediation determination, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority.

Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

Ground Lease” has the meaning set forth in the Preamble hereof.

Ground Lease Commencement Date” has the meaning set forth in the Preamble hereof.

Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes

 

4


associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

Hazardous Substances Law” means the published cleanup standards of any Governmental Authority with jurisdiction over the Site and any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law and similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including, but not limited to, the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent they relate to the handling of and exposure to Hazardous Substances.

Improvements” means any and all improvements made by Tenant, in its sole discretion, to the Site.

Initial Term” has the meaning set forth in Section 3.1.

Landlord” has the meaning set forth in the Preamble hereof.

Landlord Estoppel” has the meaning set forth in Section 23.1l(a).

Landlord Indemnitee” has the meaning set forth in Section 9.1.

Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, affiliates, invitees, agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Site and/or Landlord’s Improvements.

Landlord’s Event of Default” has the meaning set forth in Section 16.1.

Landlord’s Improvements” has the meaning set forth in Section 6.1.

Leasehold Lenders” has the meaning set forth in Section 23.1.

Leasehold Loan” has the meaning set forth in Section 23.1.

Leasehold Mortgage” has the meaning set forth in Section 23.1.

 

5


Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

Minerals” has the meaning set forth in Section 8.3(b).

New Lease” has the meaning set forth in Section 23.9(a).

Non-Disturbance Agreement” has the meaning set forth in Section 23.1l(c).

Original Ground Lease” has the meaning set forth in the Recitals hereof.

Party” or “Parties” has the meaning set forth in the Preamble hereof.

Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

Property Taxes” means all real (immovable) and personal (movable) property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

Removal Period” means the one three hundred sixty-five (365) day period that is required by Tenant to remove any and all of Tenant’s Property, including the Facilities and/or Improvements, from the Site in accordance with Section 7.1.

Rent” has the meaning set forth in Section 4.4.

Site” means the real (immovable) property of approximately eight hundred forty (840) acres described in the legal description set forth in Exhibit 1 and illustrated by the Survey Map attached as Exhibit 2, including any waterway areas, upon which the Facilities and other Improvements will be located and which real (immovable) property is owned by the Landlord.

Surface Waiver” has the meaning set forth in Section 8.3(b).

Survey Map” means the boundary survey of the Site, dated September 31, 2022, by Lonnie G. Harper & Associates, Inc., attached as Exhibit 2.

Tenant” has the meaning set forth in the Preamble hereof.

Tenant Estoppel” has the meaning set forth in Section 23.1l(b).

 

6


Tenant Indemnitee” has the meaning set forth in Section 9.3.

Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Site by or on behalf of the Tenant, including the Facilities and any Improvements.

Term” has the meaning set forth ion Section 3.2(a).

1.2 Interpretation. Unless the context otherwise requires:

(a) Words singular and plural in number will be deemed to include the other and pronouns having a masculine or feminine gender will be deemed to include the other;

(b) Any reference to this Ground Lease or any other contract or agreement in respect of the Site means such agreement and all schedules, exhibits and attachments thereto as may be amended, supplemented or otherwise modified and in effect from time to time, and shall include a reference to any document which amends, modifies or supplements it, or is entered into, made or given pursuant to or in accordance with its terms;

(c) The terms “hereof,” “herein,” “hereby,” “hereto” and similar words refer to this entire Agreement and not any particular Section, subsection or other subdivision of, or Exhibit, appendix or schedule to, this Ground Lease;

(d) The terms “include” and “including” shall be construed as being at all times followed by the words “without limitation” or “but not limited to” unless the context specifically indicates otherwise;

(e) References to “Article,” “Section” or “Exhibit” are to this Ground Lease unless specified otherwise;

(f) References to any law, statute, rule, regulation, notification or statutory provision (including Applicable Laws) shall be construed as a reference to the same as it may have been, or may from time to time be, amended, modified or re-enacted;

(g) References to any Person shall be construed as a reference to such Person’s successors, heirs and permitted assigns; and

(h) The word “or” will have the inclusive meaning represented by the phrase “and/or”.

2. Ground Lease Premises.

2.1 Date. The date of this Ground Lease is the Ground Lease Commencement Date. The Parties agree and acknowledge that on the Ground Lease Commencement Date the Tenant will assign this Ground Lease to Cameron Land Ventures, LLC.

 

7


2.2 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of the rents and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does lease to the Tenant and the Tenant hereby leases from the Landlord, the Site and Landlord’s Improvements.

2.3 Servitudes. In addition, the Landlord or its Affiliates, as applicable, shall without cost to the Tenant, grant from time to time to the Tenant and others designated by the Tenant any easements, servitudes, and rights of way for access and electricity, communications, gas, water, sewer, and other utility lines, products and materials from and to the Site over land and waterways that are adjacent to the Site and controlled by the Landlord or its Affiliates, sufficient to permit the Tenant to accomplish its purposes in connection with the Improvements and the Facilities.

3. Term

3.1 Initial Term. The initial term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on the thirtieth (30th) anniversary of the last day of the month immediately preceding the Ground Lease Commencement Date (the “Initial Term”).

3.2 Extensions.

(a) In consideration of and conditioned upon there being no uncured Event of Default on the part of the Tenant at the time an option is exercised, the Landlord hereby grants unto the Tenant the option to lease the Site for four (4) additional ten (10) year terms. If the extension option is exercised in accordance with Section 3.2(b), the first of said additional terms shall commence upon the expiration of the Initial Term and extend for a period of ten (10) years and each of said additional terms shall commence upon the expiration of the then-current additional term and extend for a period of ten (10) years. Each of such additional terms is referred to herein as an “Extended Term” and, collectively, the Initial Term and any Extended Terms are referred to herein as the “Term”.

(b) The option to extend this Ground Lease of the Site as set forth in Section 3.2(a) must be exercised in each case, if at all, by written notice from the Tenant to the Landlord on or before the date that is three (3) months prior to the expiration of the Initial Term or the then-current Extended Term, as applicable. The failure of the Tenant to timely exercise the first Extended Term or any subsequent Extended Term shall automatically terminate the right of the Tenant to exercise its option to lease the Site in any subsequent Extended Term.

(c) All the terms and conditions of this Ground Lease shall be applicable to any Extended Term and the Rent payable by the Tenant for any Extended Term shall be in accordance with the provisions set forth in Article 4.

 

8


4. Rent.

4.1 Base Rent. Commencing upon the Ground Lease Commencement Date and continuing through the earlier of (1) eighteen (18) months following the Ground Lease Commencement Date or (2) the date the Tenant provides written notice to the Landlord that Tenant has completed its environmental site preparation work (the “Base Rent Adjustment Date”), the base rent for the Site (“Base Rent”) shall BE [***] per annum, payable in equal installments of [***] per month and after the Base Rent Adjustment Date shall thereafter be [***] per annum, payable in equal installments of [***] per month, adjusted upward five years after the date on which the Base Rent increases to [***] per annum and every five (5) years thereafter during the Term by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment during any Adjustment Period (as defined below) of greater than [***]. The period from the Base Rent Adjustment Date through the date five years thereafter, and each five (5) year period thereafter shall be defined herein as an “Adjustment Period.” Any upward adjustment based on a CPI Percentage Increase (as defined below) to any payment under this Ground Lease shall hereinafter be referred to as a “CPI Adjustment.” Except for the first payment of Base Rent hereunder on the Ground Lease Commencement Date, Base Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month; provided, however, that: (i) the first payment of Base Rent shall be due ten (10) days following the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first day of the month, the first payment of Base Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; and (ii) the first payment of Base Rent due upon the commencement of any new Adjustment Period will be owed and paid one month after the commencement of that Adjustment Period in order to permit the Tenant to calculate the CPI Percentage Increase, as set forth below and (iii) the last payment of Base Rent shall be in a prorated amount for the period of time between the immediately preceding first day of the month and the last day of the Term.

4.2 CPI Adjustment. If the CPI Percentage Increase (as defined below) is more than [***] for the relevant Adjustment Period, then the Rent payable during that Adjustment Period shall be adjusted upward by a percentage equal to the CPI Percentage Increase (as defined below) applicable to such Adjustment Period, but not to exceed an adjustment during any Adjustment Period of greater than [***]. The term “Consumer Price Index” shall mean the unadjusted Consumer Price Index for All Urban Workers, U.S. City Average, All Items, 1982-84=100, calculated and published by the United States Department of Labor, Bureau of Labor Statistics. The “CPI Percentage Increase” shall mean, with respect to any Adjustment Period, [***].

 

9


For the avoidance of doubt, no CPI Adjustment shall be made to any payment due under this Ground Lease for any Adjustment Period if the result of such CPI Adjustment would be to (a) reduce the amount of such payment to an amount that is less than the amount of such payment due for the immediately preceding Adjustment Period or (b) to raise the amount of such payment to an amount that is greater than [***]. For illustrative purposes only, [***]. The CPI Percentage Increase for any Adjustment Period shall be calculated by the Tenant, and the Tenant shall deliver written notice to the Landlord describing such calculation in reasonable detail (a “CPI Notice”) no later than thirty (30) days after the commencement of any Adjustment Period. If the Landlord disagrees with the Tenant’s calculation of the CPI Percentage Increase, then the Landlord shall deliver to the Tenant written notice, describing the basis for such disagreement in reasonable detail (a “CPI Disagreement Notice”), not later than thirty (30) days after delivery of the CPI Notice. If the Landlord fails to deliver a CPI Disagreement Notice within thirty (30) days after delivery of any CPI Notice, then the Landlord shall be conclusively deemed to have agreed with the calculation of the CPI Percentage Increase set forth in such CPI Notice.

4.3 Due Date. Except as otherwise provided in this Ground Lease, all Base Rent payments shall be due in advance on the 1st calendar day of each month and payable by the 15th calendar day of each month during the entire term of this Ground Lease. If the 15th calendar day of a month falls on a day that is not a Business Day, then Base Rent shall be payable on the following Business Day.

4.4 Additional Rent. In addition to the Base Rent, Tenant shall pay to Landlord [***] of the gross rental income received each calendar year by Tenant from third party leases of land forming a portion of the Site in excess of the amount of the Base Rent payable for such portion of land, on a per-acre basis (“Additional Rent” and, together with the Base Rent, the “Rent”). Additional Rent for each calendar year will be calculated and paid by Tenant to Landlord within ninety (90) days of the end of such applicable calendar year throughout the Term. Landlord shall receive proof of all rental income each year used to calculate Additional Rent.

4.5 Place of Payment. Except as otherwise provided herein, Rent shall be payable by check or wire transfer at the address or via wire instructions as the Landlord may specify in writing to the Tenant and the Tenant deem acceptable, from time to time.

5. Net Lease; Taxes and Utility Expenses.

5.1 Net Lease. This Ground Lease is a net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs, if any, of every kind and nature whatsoever relating to the Site except as expressly otherwise provided in this Ground Lease.

 

10


5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and Governmental Approval fees applicable to the Facilities during the Term.

(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on or related to the Site during the Term (prorated on the basis of a 365-day year to account for any fractional portion of a fiscal tax year included in at the commencement or expiration of the Term). The Landlord shall promptly provide all Property Tax bills to the Tenant when they become available. Upon the latter of (i) one (1) month after receipt of such Property Tax bill from the Landlord or (ii) the due date of any such Property Taxes, the Tenant shall provide the Landlord with reasonable written evidence from the Cameron Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

(c) The Landlord shall provide written notice to the Tenant of its receipt of any oral or written notice of any audit, examination, claim or assessment relating to Property Taxes on or related to the Improvements within ten (10) Business Days following receipt of such notice. At the Tenant’s request, the Landlord shall reasonably cooperate with the Tenant to initiate any claim and commence proceedings with the appropriate Governmental Authority to contest, resolve, appeal, defend and settle any such audit, examination, claim or assessment, as applicable, all at the Tenant’s direction and sole cost and expense. The Landlord and the Tenant shall otherwise reasonably cooperate to minimize assessed value of the Improvements and underlying real property, including through coordination with the Cameron Parish Tax Collector’s Office.

5.3 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost, electricity, telephone, water, sewerage, gas, and other utility services to the Site; provided, however, the Landlord shall cooperate and, to the extent reasonably needed, facilitate the contracting of any easements, servitudes and/or rights of way, and grant easements, servitudes and rights of way in accordance with Section 2.3, as required by the Tenant for such utility connections and/or services.

6. Tenant and Landlord Improvements.

6.1 Landlord’s Improvements. “Landlord’s Improvements” are any and all improvements to the immovable property of the Site and any and all movable property in existence on the Site at the time of the Ground Lease Commencement Date. There are no Landlord’s Improvements. For the avoidance of doubt, as of the expiration of the Term or earlier termination of this Ground Lease, the Tenant shall have no obligation to restore, return or provide any further consideration for any Landlord’s Improvements.

 

11


6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install on the Site, any Improvements during the Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. During the Term, the Tenant shall be permitted to make any changes, improvements or alterations to the Site, including the Facilities, the Landlord’s Improvements and any Improvements to the Site, as long as the changes, alterations and/or Improvements comply with Applicable Laws.

6.3 Governmental Approvals. The Landlord will cooperate and assist (and never oppose) the Tenant in obtaining any and all Governmental Approvals deemed necessary by the Tenant for the Facilities and all other Improvements to the Site, including with respect to Governmental Approvals from the US Army Corp of Engineers, Louisiana Department of Natural Resources, Louisiana Department of Environmental Quality, Federal Energy Regulatory Commission and the Department of Energy. The Landlord will hereafter continue to be obligated to execute appropriate documentation to waive its right to require wetlands mitigation to be completed on the Site or other real (immovable) property owned by the Landlord, in such form as necessary to allow the Tenant to complete such wetlands mitigation at locations other than other real (immovable) property owned by the Landlord.

6.4 Tenant’s Property. Tenant’s Property shall at all times be and remain the sole property of the Tenant.

6.5 Maintenance of Improvements.

(a) Tenant’s Obligation to Maintain. During the Term, the Tenant will keep in reasonably good state of repair the Facilities, the Improvements, open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Site by the Tenant, and the Tenant will, in its sole discretion and cost, repair such property as often as may be necessary in order to keep the Facilities and the Improvements in reasonably good repair and condition, except as set forth in Section 6.5(b).

(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease, the Landlord has no obligation to maintain the Site, Improvements and/or Landlord’s Improvements (if any) during the Term. The Landlord further agrees that there will be no Landlord improvements on the Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

7. Tenant’s Surrender of Site.

7.1 Surrender at End of Ground Lease. Subject to Section 6.4 and subject and subordinate to Section 23 and the rights of any Leasehold Lender under any Leasehold Mortgage, the Tenant shall and will on the last day of the Term, surrender and deliver the Site to the Landlord, in good condition as is reasonably practicable (except as provided in Section 6.5 or Section 13), excepting normal wear and tear. If this Ground Lease is terminated for any reason or upon the

 

12


expiration of the Term, the Tenant shall in good faith proceed with (i) any removal of the Facilities and any and all Improvements and (ii) restoration, if any, of the Site to its condition prior to construction of the Facilities and/or Improvements, including with respect to any movement of dirt, dredging or other activities performed by the Tenant as described in Section 8.3(a), in accordance with Applicable Law. During the Removal Period, the Tenant shall have all access rights to the Site that are necessary to remove any and all of the Tenant’s Property, including the Facilities and/or Improvements. The Tenant shall also comply as required by any federal regulations of the Federal Energy Regulatory Commission or any other federal authority with respect to the Facilities on the Site.

7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date the Tenant shall assume full dominion, control and responsibility for the Site, except to the extent specifically provided herein, to the extent provided under LSA - R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real (immovable) or personal (movable) property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its officers, representatives, agents, or employees or the Landlord’s misrepresentations or its breach of or default under this Ground Lease.

7.3 Holding Over. Except for the Removal Period, if the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, and shall not constitute a renewal or extension of the Term.

8. Use.

8.1 Permitted Uses; Compliance with Laws; Permits. The Tenant may use the Site for any and all uses desired by the Tenant in compliance with all Applicable Laws. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the construction, operation, and maintenance of the Facilities, the Improvements and/or for the Tenant’s use or activities on the Site. The Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Facilities, the Improvements, and the security of the Site, including the timely filing, implementation, and enforcement of any security plan required by Applicable Laws. Any fine or penalty imposed by any Governmental Authority solely caused by the failure of the Tenant to comply with this Section 8.1, including any fine or penalty imposed upon the Landlord as owner of the Site as solely caused by the failure of the Tenant to comply with this Section 8.1, shall be the sole responsibility of the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall indemnify and hold harmless the Landlord from the payment of any such fine or penalty, and the Tenant may pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord.

 

13


8.2 Use of Water Frontage. The Tenant shall have any and all rights, including any and all riparian rights, to use any and all of the water frontage and water bottom of the Site, including the Landlord’s Improvements (if any) and the area between the water frontage of the Site to the Ship Channel and/or the area between the water frontage of the Site to Gulf of Mexico, for mooring of vessels and/or for any and all other uses allowed under Applicable Laws; and the Landlord shall not have the right to use the water frontage of the Site, including all aforementioned areas, for mooring of vessels or any other uses without the prior written consent of the Tenant. It is expressly understood that the Tenant’s consent shall be given or withheld in the Tenant’s sole discretion, and if granted, would be in accordance with any security plan of the Tenant.

8.3 Dirt Moving Activities; Permits; Timber.

(a) Without prejudice to its obligations under Section 7.1, the Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Site, to the Site, and from portions of the Site to other portions of the Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Site and may do so in its discretion. The Tenant shall have the right to remove soil and spoil from, and to add fill to, the Site and to dredge the slip and turning basin and dredge and widen the Calcasieu Ship Channel, and deposit the dredge spoils on the Site (as allowed by Applicable Law), in each case in connection with the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of the Facilities, and for the purpose of constructing, creating, expanding, operating and maintaining a marine terminal and ship turning basin. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Site, including without limitation, for any Improvements, reclamation of lands, erosion control, attainment of spoil, easements/servitudes and/or rights of way; provided that all costs associated with such efforts shall be the responsibility of the Tenant. Except only as provided in Section 8.3(b), the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Site, and all other rights on and to the Site. Any activities of the Landlord and/or its lessees or assignees or any other party shall not adversely affect the Site or the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any way. Nothing herein is intended to preclude the Landlord, from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation. The Tenant may freely remove any timber which is standing or lying on the Site as the Tenant deems necessary for the Tenant’s intended use of the Site. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights, which includes carbon capture and sequestration, below the surface of the Site, including any injection well of any kind or nature below the surface of the Site.

(b) To the extent the Landlord holds any rights to oil, gas, or other minerals, which includes carbon capture and sequestration (“Minerals”) in the Site, Landlord waives any and all rights of the Landlord or its lessees or assignees to use the surface of the Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the term of this Ground Lease, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means consistent with the terms and

 

14


conditions of this Section 8.3(b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any way.

8.4 Crossing. The Landlord shall assist the Tenant in the Tenant’s efforts to develop, at the Tenant’s cost, any roads and/or crossings or other Improvements across the Site and boundary lines of the Site to the adjacent land, including relocation of utilities, providing culverts for storm water drainage, and any other Improvements. The Tenant or others, excluding the Landlord, will pay the cost to relocate or modify the infrastructure for these roads and/or crossings and/or other Improvements. The Landlord shall not be required to incur any costs or expenses in its efforts to assist the Tenant.

8.5 Pipelines; Rights of Way. If at any time the Tenant notifies the Landlord that the Facilities require an off-Site pipeline and/or pipeline servitude for the development, construction or operation of the Facilities at the Site, the Landlord shall, with respect to its own real (immovable) property, grant and, with respect to any other property, use commercially reasonable efforts to cause the applicable landowners and Governmental Authorities to grant, the pertinent approvals to achieve, site, construct and operate and maintain the pipeline and/or pipeline right of way, as directed and on such terms and conditions as reasonably requested by the Tenant. The Landlord shall not be required to incur any costs or expenses in its efforts to assist the Tenant.

9. Indemnification.

9.1 Tenant’s General Agreement to Indemnify. The Tenant releases the Landlord, its officers, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, witness fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Landlord Indemnitee arising out of (i) the use or occupancy of the Site by the Tenant, its officers, representatives, agents, and employees, (ii) the construction or operation of the Facilities by the Tenant, its officers, representatives, agents, and employees, (iii) any claim arising out of the use, occupancy, construction or operation of the Site by the Tenant, its officers, representatives, agents, and employees, and (iv) activities on or about the Site by the Tenant, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, operation, maintenance, or repair of the Site, the Facilities, or the Improvements, by the Tenant, its officers, representatives, agents, and employees; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Landlord Indemnitee shall be excluded from this indemnity. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9.2 and 9.4 and not this Section 9.1.

 

15


9.2 Tenant’s Environmental Indemnification. For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with all Environmental Laws applicable to the Tenant, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Tenant agrees to indemnify and hold harmless the Landlord Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorney, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including, without limitation, a Governmental Authority), to the extent arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth above in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Site or any violation of any Environmental Law with respect to the Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, and maintenance activities or facilities and not caused by the Landlord’s Activities or Landlord’s Improvements.

9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Site by the Landlord, its officers, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Site by the Landlord, its officers, representatives, agents, and employees, and (iii) activities on or about the Site by the Landlord, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope but not be limited to any and all claims or actions for wrongful death, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.4 and not this Section 9.3.

9.4 Landlord’s Environmental Indemnification.

(a) For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorneys, accounting, consulting, engineering, and other fees and

 

16


expenses), which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances; (ii) any actual or alleged violation of Environmental Laws, in the case of each of subclauses (i) and (ii), where the presence, discharge or release of such Hazardous Substances or violation of Environmental Law arises or occurs (1) at, on or from the Site on or prior to the Ground Lease Commencement Date or (2) at, on or from the Site or any other site as a result of or relating to the Landlord’s Activities or facilities or Landlord’s Improvements, whether before, on or after the Ground Lease Commencement Date; (iii) the Landlord’s breach of the covenant set forth above in this Section 9.4; or (iv) any environmental condition of contamination on the Site or any violation of any Environmental Law with respect to the Site to the extent occurring after the Ground Lease Commencement Date and caused by the Landlord’s Activities or facilities.

(b) If Hazardous Substances become present or are discharged onto the Site as a result of the Landlord’s Activities or otherwise exist at the Site on or prior to the Ground Lease Commencement Date, the Tenant shall so notify the Landlord in writing as soon as practicable after the Tenant’s discovery thereof. Except with respect to Hazardous Substances that become present or are discharged onto the Site as a result of the Landlord’s Activities, such discovery and notice to the Landlord must occur within the Initial Term of this Ground Lease for the Landlord to have any obligation to perform any Corrective Measures (as hereinafter defined). Except as provided in the following sentence, upon receipt of such notice from the Tenant, the Landlord shall have a reasonable period of time to undertake, at its own expense, but subject to a limit of $5,000,000, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority (“Corrective Measures”), except that such Corrective Measures shall not unreasonably interfere with the construction, operation or maintenance of the Facilities and/or interfere the Improvements by the Tenant. At its discretion, upon written notice to the Landlord, the Tenant shall have the right to undertake such Corrective Measures and the Landlord shall reimburse the Tenant up to a total amount of $5,000,000 (or the Tenant may offset against Rent) for its reasonable and necessary documented costs therefor within thirty (30) days after receipt of an invoice by the Landlord (including any costs associated with the work stoppage or interference with the ability of any Facility Contractor to perform its respective obligations under the Facility Contracts (including mobilization and de-mobilization costs, suspension costs, storage costs, rescheduling penalties, and all other direct and indirect costs incurred by the Tenant or any Facility Contractor (and its respective subcontractors) as a result of any delay caused by such Corrective Measures)). The Party not controlling the Corrective Measures under this Section 9.4(b) shall have a reasonable right of participation in the Corrective Measures, including the right to (i) receive copies of material reports, work plans and correspondence relating to the Corrective Measures, (ii) review and comment on draft reports and work plans (and all prompt and reasonable comments shall be considered and addressed by the controlling Party in good faith), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.4(b) shall not supersede or diminish the provisions or the Landlord’s obligations under Section 9.4(a).

 

17


9.5 Survival of Indemnities. The foregoing indemnities shall survive the Term and any Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

10. Insurance.

10.1 Tenant Insurance. The Tenant shall carry or cause to be carried commercial general liability insurance with respect to the Site and the uses and activities of the Tenant thereon with minimum limits of $[***]. The Tenant may elect to be self-insured in amounts greater than those minimum limits. In the event the Tenant procures commercial general liability insurance, the Landlord will be named as an additional insured.

10.2 Landlord Insurance. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Site and/or any activities of the Landlord with respect to the Site in its reasonable business discretion. The Landlord may elect to be self-insured.

11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. The Landlord shall not create or permit to be created or to remain in connection with the Site, the Facilities, the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Site or upon the Landlord’s interest in the Site or upon the Tenant’s interest in its leasehold of the Site, in accordance with Section 11.2.

11.2 Discharge of Liens.

(a) If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

(b) If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge

 

18


of such Lien by deposit or by bonding proceedings. Any amount so paid by the non-responsible Party and all costs and expenses incurred by the non-responsible Party in connection therewith, including reasonable attorneys’ fees together with interest thereon at one percent (1%) per annum above the Wall Street Journal Prime Rate of interest published from time to time in the Wall Street Journal, from the respective dates of the non-responsible Party’s making of the payment or incurring of the cost and expense, shall constitute either additional rent payable by the Tenant under this Ground Lease or an offset against Rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Site, including without limitation, any liabilities, obligations and/or debts owed to laborers, vendors, brokers, materialmen, and other service providers, and then offset against the Rent any such amount(s) paid by the Tenant.

12. Entry on Premises by Landlord, Etc.

The Landlord and its representatives shall have no right to enter the Site, except as specifically authorized from time to time in advance in writing by the Tenant after written notice to the Tenant of such request by the Landlord; and such authorization shall be in the Tenant’s sole discretion, and if/when granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of the Tenant. Such entry on the Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions such that access to certain sections of the Site will be restricted.

13. Destruction by Fire or Other Casualty.

If the Facilities or any Improvements erected on the Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the willful misconduct of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Facilities or the Improvements. In the event that the Tenant so decides not to restore or reconstruct the Facilities or the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove any ruins or rubble remaining on the Site at the Tenant’s sole cost and expense.

14. Assignment; Subleasing; Right of First Refusal.

14.1 Restrictions on Landlord. The Landlord shall not assign this Ground Lease or sell the Site, in whole or in part, (including without limitation by transfer of control or otherwise) without the prior written consent of the Tenant, which consent shall not be unreasonably withheld, delayed, or conditioned, except with respect to the Tenant’s right of first refusal as set forth in Section 14.3. This Ground Lease shall inure to the benefit of and shall be binding upon the Landlord’s permitted assigns.

 

19


14.2 Restrictions on Tenant. Subject to the provisions of Section 23, the Tenant shall not assign this Ground Lease, in whole or in part, without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least ten (10) days prior written notice of any proposed assignment, together with a copy of the proposed assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing, including to a Leasehold Lender, (ii) to a Leasehold Lender or any purchaser upon a foreclosure of a Leasehold Mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a Leasehold Mortgage, (iii) to any Affiliate or member of the Tenant, (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder or (vi) to Cameron Land Ventures, LLC. The Tenant shall not sublease all or any portion of the Site without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned.

14.3 Right of First Refusal. During the Term of this Ground Lease, the Landlord may not transfer a portion of the Site and may only transfer the entire Site through a bona fide sale in exchange for a sum certain of money. If the Landlord, during the Term of this Ground Lease, receives a Bona Fide Offer from a third party to buy or acquire all or any portion of the Site separately or as a part of a larger parcel of which the Site is a part, the Landlord will promptly, within ten (10) Business Days of such receipt, give written notice to the Tenant of the terms of the Bona Fide Offer made or received, including the cash price attributable to the Site. If the sale is a tract of which the Site is a part, then the cash price attributable to the Site will be that part of the cash price multiplied times a fraction, the denominator of which is the total number of acres in the Site and the numerator of which is the total number of acres in the larger tract to be sold. The notice shall also state the other terms and conditions of the proposed sale and the Landlord’s willingness to sell for that cash price and on those terms. Upon receiving the notice, the Tenant may exercise the right, in the manner specified below, to purchase either the property described in the Bona Fide Offer or the Site (or part thereof) at the stated cash price in the Bona Fide Offer. This Section 14.3 does not apply to transfers pursuant to successions or donations executed in accordance with Louisiana law.

14.4 Exercise of Right of First Refusal. If the Tenant elects to purchase the property or Site described in the Bona Fide Offer under the provisions of Section 14.3, the Tenant must notify the Landlord of such election, doing so in writing delivered to the Landlord within thirty (30) Business Days after the date of the Landlord’s written notice to Tenant of the Bona Fide Offer. If the Tenant elects to refuse the Bona Fide Offer, the Tenant need take no action whatsoever; further, if the Tenant fails to deliver to the Landlord a notice of the Tenant’s election within the time required for such notice, the Tenant will be deemed to have refused the Bona Fide Offer. If the Tenant refuses, or is deemed to have refused, the Bona Fide Offer, the Landlord is free to sell the property pursuant to the Bona Fide Offer subject to this Ground Lease and any Leasehold Mortgage, any New Lease and any Non-Disturbance Agreement, and continuation of the leasehold interest created by this Ground Lease and any New Lease.

 

20


14.5 Continuation of Right. If for any reason the Site is not sold by the Landlord following a Bona Fide Offer from a third party, the right of first refusal granted and described in the preceding Sections 14.1 through 14.4 shall continue in full force and effect, on the same terms and conditions.

15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of fifteen (15) days after written notice thereof from the Landlord to the Tenant.

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15.1(a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Site or discharge from the Site shall not constitute an Event of Default.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages; Termination. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default, the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the Tenant shall be liable for such reasonable damages unless such Event of Default is reasonably remedied in a timely manner and all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default, together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and payable, and all costs and expenses reasonably incurred by or on behalf of the Landlord as a result of the Event of Default, including reasonable attorneys’ fees, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective and is not valid if the Landlord does not give prior written notice to the Tenant pursuant to Section 15.1.

 

21


(b) Landlord’s Right to Cure Tenant’s Event of Default. Upon the occurrence of an Event of Default of the Tenant which is not cured or having commenced curing by the Tenant within sixty (60) days as provided in Section 15.2(b), then, subject to the prior written consent of any Leasehold Lender under Section 23, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others to cure the Event of Default. The Tenant shall be responsible for all costs, including attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord.

15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Site to the Landlord, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Site and may have, hold, and enjoy the Site; and (ii) all obligations of the Tenant hereunder for additional rent or any portion thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. In the event of any termination, the Landlord shall be under a duty to seek a successor tenant. If the Landlord obtains a successor tenant during what would have been the remainder of the term of this Ground Lease, the Tenant shall receive a credit for rentals collected from said successor tenant for the remaining Term. If no successor tenant is obtained, the Tenant shall be liable for Rent obligations otherwise provided for in this Ground Lease.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

16. Events of Default of the Landlord.

16.1 Landlord’s Event of Default; Right to Cure. Any failure of the Landlord to perform and/or to comply with any of its obligations, covenants, agreements, terms, or conditions contained in this Ground Lease shall constitute a “Landlord’s Event of Default” hereunder. The Landlord shall have sixty (60) days after notice by the Tenant to the Landlord of Landlord’s Event of Default to fully cure Landlord’s Event of Default.

 

22


16.2 Tenant’s Remedies; Cure. In the event of a Landlord’s Event of Default that is not fully cured under Section 16.1, in addition to all other remedies available to the Tenant, the Tenant may cancel this Ground Lease by written notice to the Landlord. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof, and shall be immediately payable to the Tenant. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default that is not fully cured under Section 16.1.

16.3 Tenant’s Right to Cure Landlord’s Event of Default. Upon the occurrence of a Landlord’s Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord’s Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others, purchasing the required goods or services and procuring necessary insurance. The Landlord shall be responsible for all costs including attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

17. Mutual Obligations.

17.1 Late Charges; Interest. If any Rent or other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of ten (10) days after receipt of written notice, such sum shall bear a late charge equal to one percent (1.0%) of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

 

23


17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise (excluding, however, specific performance against the Tenant) and the exercise or beginning of the exercise by the Parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by email or United States registered or certified mail, return receipt and signature requested, postage prepaid, to the Parties at the following numbers and addresses:

 

  To the Tenant:

Cameron Land Ventures, LLC

 

1001 19th Street North

 

Suite 1500 Arlington, VA 22209

 

Attention: General Counsel

 

Email: [***]

 

  To the Landlord:

J.A. Davis Properties, LLC

 

1423 W. Prien Lake Road

 

Lake Charles, LA 70601

 

Attention: [***]

 

Email: [***]

 

  With a copy to:

Stockwell, Sievert, Viccellio, Clements &

 

Shaddock, LLP

 

One Lakeside Plaza

 

Lake Charles, LA 70601

 

Attention: [***]

 

Email: [***]

or to such other numbers or addresses as either above designated recipients may from time to time designate by written notice to the other designated recipient hereto at least fifteen (15) days in advance of an effective date stated therein.

18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mail, return receipt and signature requested, postage prepaid.

 

24


19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable possession of the Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Site during the Term and the Removal Period of this Ground Lease without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord. This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow compatible use of the remainder of their property adjacent to the Site and will not create or allow the creation of a visual, olfactory or auditory nuisance on said remainder of their property.

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that: (i) it is the sole owner of good title to all of the Site; (ii) the Site is subject to no Liens, privileges, encumbrances, defects in title, servitudes, easements, restrictions, dedications, leases, mineral leases, reservations or other exceptions to title; (iii) during the Term it shall not encumber the Site; (iv) it is authorized to make this Ground Lease for the Term; (v) the provisions of this Ground Lease do not and will not conflict with or violate any of the provisions of existing agreements between the Landlord and any third party; and (vi) the Landlord will deliver the Site free of all tenants and occupants and claims thereto.

20. Eminent Domain.

20.1 Complete Condemnation. If, during the Term, the whole of the Site shall be taken under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking) by any public or private authority, then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided that the Tenant shall share in the condemnation award as provided herein. The Tenant may continue to occupy the Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Site from and after the date of such taking.

20.2 Partial Condemnation. If, during the Term, any public or private authority shall, under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking), makes a taking resulting in the reduction of the surface area of the Site by fifteen percent (15%) or more, or of fifteen percent (15%) or more of the value of the Facilities, the Improvements or the Landlord’s Improvements, or resulting in material interference to the Tenant’s ability to use in a commercially reasonable manner the remainder of the Site, the Facilities, the Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of

 

25


the exercise of its election within one-hundred twenty (120) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2, the Term shall cease and this Ground Lease shall terminate as of the last day of the calendar month in which such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant, and the Tenant shall share in the condemnation award as provided herein.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the Term shall continue in full force and effect, and the Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete taking pursuant to Section 20.1, the Tenant will be entitled to receive the portion of the condemnation award (or settlement) attributable to (i) the value of the Facilities, the Improvements and Landlord’s Improvements, and fixtures and other property located on the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, plus (iii) other compensation or benefits paid as a consequence of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking (if any such compensation or benefits are paid by the applicable taking authority) and the Landlord shall be entitled to recover that portion of the condemnation award (or settlement) fairly attributable to the value of the land taken. In the event Tenant’s Property, the Improvements or the Facilities are not taken, the Tenant shall not be entitled to any portion of the award, and in the event no Landlord’s property is taken, the Landlord shall not be entitled to any portion of the award. In the event of a partial taking of the Improvements, Tenant’s Property and/or Facilities, the entire award or settlement shall be paid to the Tenant. In the event of a partial taking of the Site, the Tenant will be entitled to receive the portion of the award attributable to (i) the value of the portion of the Facilities, Improvements and Tenant’s Property located in the portion of the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, plus (iii) damage to the remaining Facilities, and the Tenant will promptly restore the remaining portion of the Facilities to the extent of the award payable to the Tenant. Nothing contained herein shall prohibit the Tenant’s claiming relocation damages or damages for lost profits or loss of leasehold advantage against the taking authority in any appropriate proceeding.

21. Temporary Taking or Other Deprivation.

If, during the Term, (i) less than all of the Landlord’s title to all or any portion of the Site is taken for temporary use or occupancy, or (ii) any public or private authority takes any action not resulting in a taking of all or any portion of the Site but resulting in a right to compensation therefor, such as changing of the grade of any street upon which the Site abuts, then, except as otherwise provided in Section 20, the Tenant shall be entitled to make claim for, recover, and retain all awards, whether pursuant to judgment, agreement, or otherwise, recoverable in connection therewith.

 

26


22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure; provided that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section 23 shall govern and control.

23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage, or any agent or trustee therefor, that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant. The term “Leasehold Mortgage” shall mean, at any point in time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Site and this Ground Lease. It is acknowledged and agreed that, during the Term, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the Term, the Tenant shall provide the Landlord with written notice of the identity, contact information and address for each Leasehold Lender (or the agent authorized to act on behalf of the Leasehold Lender), such notice to be provided to the Landlord by the Tenant within no less than a calendar year within which the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

23.2 Right to Perform for Tenant; Right to Cure.

(a) In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and the Landlord shall accept such performance by Leasehold Lender with the same force and effect as if furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender

 

27


shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing.

(b) If any default in the performance of an obligation of the Tenant under this Ground Lease is not susceptible to being cured by Leasehold Lender, the Landlord shall have no right to terminate this Ground Lease with respect to such default and such default shall be deemed waived for the benefit of Leasehold Lender only; provided that:

(i) Leasehold Lender shall have commenced to cure (i) any other non-payment default of the Tenant that is susceptible to being cured by Leasehold Lender and (ii) any default in the payment of any portion of Rent, in each case, within the time periods prescribed under Section 23.2(a);

(ii) Leasehold Lender (or its designee) shall have commenced to acquire the Tenant’s interest in this Ground Lease and the Site or to commence foreclosure or other appropriate proceedings under the Leasehold Mortgage within the time periods prescribed under Section 23.2(a);

(iii) if Leasehold Lender (or its designee) shall acquire the Tenant’s interest in this Ground Lease and/or the Site, Leasehold Lender (or its designee) shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition; and

(iv) if any third party shall, by foreclosure or dation en paiement under the Leasehold Mortgage or by assignment or other transfer from Leasehold Lender, acquire the Tenant’s interest in and to the Site under this Ground Lease, such third party shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by a third party with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition.

However, if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then notwithstanding any provision in this Section 23 to the contrary, the Landlord may exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

 

28


23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’s prior written consent, and any such action taken without Leasehold Lender’s consent shall not be binding on the Tenant or Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.4 Delivery of Notices. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including, without limitation, any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been delivered to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in writing to the Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’s interests in the Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including, without limitation, the acquisition of the Tenant’s interest in this Ground Lease and the Site created thereby in a transaction described in this Section 23 or the taking of possession of the Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender; provided that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Site.

 

29


23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2, the purchaser at any sale of this Ground Lease and the interests in and to the Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including, without limitation, power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Site thereby created under any instrument of assignment or transfer in lieu of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Site thereby created.

23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, substantially all, or any part of the Site or the Tenant’s Facilities. Rent shall continue to be due and payable as set forth in this Ground Lease.

23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent domain proceeding of all, substantially all, or any part of the Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Facilities, the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Site created by this Ground Lease and the value of the leasehold improvements located on the Site, up to an amount equaling the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Facilities and/or the Tenant’s interest in, under and to this Ground Lease; provided that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under applicable law to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this Ground Lease. In the event of a taking of a portion of the Site, the Rent shall be reduced pro rata based upon the portion of the Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease.

 

30


23.9 New Direct Lease.

(a) If this Ground Lease is canceled or terminated for any reason (except in connection with a Bankruptcy Proceeding, for which the provisions of Section 23.10 are hereby agreed upon by the Landlord and the Tenant), and provided that Leasehold Lender has (i) commenced to cure and continues diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, and (ii) cured any payment default in respect of any portion of Rent, the Landlord hereby agrees that the Landlord shall, upon Leasehold Lender’s written election within one hundred twenty (120) days of such cancellation or termination, promptly enter in a new, direct lease with Leasehold Lender (or its nominee or any other party which Leasehold Lender may designate, including without limitation, the Tenant) with respect to the Site on the same terms and conditions as this Ground Lease (a “New Lease”), it being the intention of the parties to preserve this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Said New Lease shall be superior to all rights, liens and interests intervening between the date of this Ground Lease and the granting of the New Lease and shall be free of any and all rights of the Tenant under this Ground Lease.

(b) The Tenant and the Landlord acknowledge and agree that Leasehold Lender shall have the right to encumber such direct New Lease and the estate created thereby with a deed of trust or a mortgage (as the case may be) on the same terms and with the same lien priority as the Leasehold Mortgage, it being the intention of the parties to preserve the priority of the Leasehold Mortgage, this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. If this Ground Lease is rejected, cancelled or terminated for any reason and Leasehold Lender, its nominee or a designee of Leasehold Lender enters into a direct lease with the Landlord with respect to the Site, the Landlord hereby agrees that it will execute such documents as Leasehold Lender may require in order to ensure that the new direct lease provides for customary leasehold mortgagee protections, including without limitation, protections similar to those contained herein.

23.10 Bankruptcy. In the event of a proceeding under the United States Bankruptcy Code (Title 11 U.S.C.) as now or hereafter in effect (a “Bankruptcy Proceeding”):

(a) If this Ground Lease is rejected in connection with a Bankruptcy Proceeding by the Tenant or a trustee in bankruptcy (or other party to such proceeding) for the Tenant, such rejection shall be deemed an assignment by the Tenant to the Leasehold Lender of the Tenant’s Property and all of the Tenant’s interest under this Ground Lease, and this Ground Lease shall not terminate and the Leasehold Lender shall have all rights and obligations of the Tenant as if such Bankruptcy Proceeding had not occurred, unless Leasehold Lender shall reject such deemed assignment by notice in writing to the Landlord within thirty (30) days following rejection of this Ground Lease by the Tenant or the Tenant’s trustee in bankruptcy. If any court of competent jurisdiction shall determine that this Ground Lease shall have been terminated notwithstanding the terms of the preceding sentence as a result of rejection by the Tenant or the trustee in connection with any such proceeding, the rights of Leasehold Lender to a New Lease from the Landlord pursuant to Section 23.9 hereof shall not be affected thereby.

 

31


(b) In the event of a Bankruptcy Proceeding against the Landlord:

(i) If the bankruptcy trustee, the Landlord (as debtor-in-possession) or any party to such Bankruptcy Proceeding seeks to reject this Ground Lease pursuant to United States Bankruptcy Code §365(h)(1), the Tenant shall not have the right to treat this Ground Lease as terminated except with the prior written consent of Leasehold Lender and the right to treat this Ground Lease as terminated in such event shall be deemed assigned to Leasehold Lender, whether or not specifically set forth in the Leasehold Mortgage, so that the concurrence in writing of the Tenant and the Leasehold Lender shall be required as a condition to treating this Ground Lease as terminated in connection with such Bankruptcy Proceeding.

(ii) Unless this Ground Lease is treated as terminated in accordance with Section 23.10(b)(i), then this Ground Lease shall continue in effect upon all the terms and conditions set forth herein, including Rent, but excluding requirements that are not then applicable or pertinent to the remainder of the Term. Thereafter, the Tenant or its successors and assigns shall be entitled to any offsets against Rent payable hereunder for any damages arising from such bankruptcy, to the extent the Tenant’s operation of business has been materially interfered with, and any such offset properly made shall not be deemed a default under this Ground Lease. The lien of the Leasehold Mortgage shall extend to the continuing possessory rights of the Tenant following such rejection with the same priority as it would have enjoyed had such rejection not taken place.

23.11 Estoppel Certificates; Non-Disturbance Agreements.

(a) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel”) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under this Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant thereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that each of this Ground Lease and the Non-Disturbance Agreement, true, correct copies of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, have not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Term is scheduled to expire, (vii) as to the Landlord’s power and

 

32


authority to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, and any Non-Disturbance Agreement, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which Landlord is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the Landlord Estoppel, the present lessor under this Ground Lease and owns good and indefeasible title to the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (xix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

(b) Within fifteen (15) days following Leasehold Lender’s or the Landlord’s written request, the Tenant shall provide Leasehold Lender with an estoppel certificate (the “Tenant Estoppel”) which shall certify to such requesting Leasehold Lender (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Landlord of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Landlord of any other conditions required under this Ground Lease, (iii) as to any existing default of the Landlord under this Ground Lease, or alternatively that the Landlord is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Landlord hereunder, and as to any existing event or condition in existence as of the date of the Tenant Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Tenant to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Tenant, (v) that this Ground Lease, a true and correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and

 

33


collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Term is scheduled to expire, (vii) as to the Tenant’s power and authority to execute the Tenant Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Tenant asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Tenant from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties, or other sums, whether or not constituting rent, due and owing as of the date of the Tenant Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which the Tenant is a party (other than those set forth on a schedule to the Tenant Estoppel), (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Tenant Estoppel, (xiv) that the Tenant is, as of the date of the Tenant Estoppel, the present lessee under this Ground Lease and holds a valid leasehold interest in the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Tenant has not assigned, sublet, hypothecated, leased, or otherwise transferred it interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Tenant’s interest in the Site, other than those set forth on a schedule to the Tenant Estoppel, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Tenant is a party or by which the Tenant is otherwise bound affecting the Tenant’s interest in and to the Site, (xvii) that the Tenant has not commenced any action or sent any notice to the Landlord for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Tenant is not, as of the date of the Tenant Estoppel, entitled to terminate, cancel, modify, or surrender this Ground Lease, and (xviii) as to such other matters related to this Ground Lease as such Leasehold Lender may reasonably determine from time to time.

(c) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall enter into a non-disturbance agreement with Leasehold Lender or its designee, in the form attached hereto as Exhibit 5 (a “Non-Disturbance Agreement”).

23.12 No Termination by Confusion. There shall be no termination by confusion of this Ground Lease or any interest in this Ground Lease or of the interests in and to the Site created thereby, by reason of the fact that this Ground Lease or such interest therein may be directly or indirectly owned by any person who shall hold any ownership interest in the Site, nor shall there be such a termination by confusion by reason of the fact that all or any part of the interests in and to the Site created by this Ground Lease may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any ownership interest in the Site or any ownership interest of the Landlord under this Ground Lease.

23.13 Landlord’s Recognition of Tenant. The Landlord hereby recognizes the Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that the Tenant acquired its interest in this Ground Lease and in and to the Site in accordance with the terms of this Ground Lease.

 

34


23.14 Agreement to Amend. The Landlord recognizes the importance of the Tenant’s ability to obtain Leasehold Mortgages, and that the provisions of this Ground Lease may be subject to the approval of a Leasehold Lender. If any Leasehold Lender should require, as a condition to such financing, any reasonable modifications of this Ground Lease, whether for purposes of clarifying the provisions of this Ground Lease or to include provisions then customary for leasehold financing transactions, the Landlord agrees to execute the appropriate amendments to this Ground Lease; provided, however, that no such modification shall, to the detriment of the Landlord, impair any of the Landlord’s rights, as reasonably determined by the Landlord or increase any of the Landlord’s obligations, as reasonably determined by the Landlord, under this Ground Lease.

23.15 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

23.16 Subordination of Landlord’s Lien. The Landlord hereby subordinates any lien or privilege it may have on any movables found from time to time in or upon the Site, including without limitation, the Landlord’s privileges pursuant to La. Civil Code articles 2707, et seq., to any Leasehold Lender’s rights under this Section 23 and the lien of any Leasehold Mortgage.

24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

24.2 Successors. The covenants, agreements, terms, provisions, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties hereto.

24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

 

35


24.6 No Oral Change or Termination. This Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties hereto with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, including the Original Ground Lease, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

24.9 Litigation. In case of any litigation between the Parties hereto regarding the subject matter hereof, the losing Party shall pay all reasonable costs and expenses (including reasonable attorneys’ fees) of the prevailing Party. The venue of any litigation shall be solely in Cameron Parish.

24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

24.11 Authority. Each of the Landlord and the Tenant represents and warrants that it has the authority to enter into this Ground Lease, that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date, (a) the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 3, evidencing its authority to execute and perform under this Ground Lease and (b) the Landlord shall deliver to the Tenant a resolution in the form attached hereto as Exhibit 4, evidencing its authority to execute and perform under this Ground Lease.

24.12 Brokers and/or Real Estate Agents. Each of the Landlord and the Tenant represents, acknowledges and agrees that it is not represented by any real estate broker/agent and that it is not responsible for payment of any commissions to any real estate brokers/agents in connection with this Ground Lease.

 

36


24.13 Legal Relationships; Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. There is no third party beneficiary of this Ground Lease, except as provided in Section 23.15 and any rights of a Leasehold Lender as provided herein. This Ground Lease is the product of the Parties joint negotiation and equal drafting thereof. The language of this Ground Lease shall be construed as a whole according to its fair meaning and not construed strictly for or against any of the Parties pursuant to any statue, case law or rule of interpretation or construction to the contrary.

24.14 Settlement Funds. The Landlord and the Tenant agree that any claims, which may exist for damage to the Site, exclusive of any improvements of the Tenant, shall be reserved to the sole benefit of the Landlord. Similar claims that may exist for damage to Tenant improvements and/or operations shall be reserved to the sole benefit of the Tenant.

24.15 Limited Recourse. The Landlord agrees that the sole recourse of the Landlord for any damages or liabilities due by the Tenant hereunder shall be limited to the assets of the Tenant, without recourse individually or collectively to the members or the Affiliates of the Tenant, the Leasehold Lenders or their respective directors, officers, agents, members, shareholders, managers, partners, employees or representatives; provided that, for the avoidance of doubt, the foregoing shall not be deemed to derogate or otherwise modify Tenant’s indemnity obligations under Article 9.

24.16. Further Assurances. In connection with this Ground Lease and the transactions contemplated hereby, each Party shall execute and deliver any additional documents and instruments and perform any additional acts that may be necessary or appropriate to effectuate and perform the provisions of this Ground Lease and those transactions, including in connection with the requests of any Financing Parties or Leasehold Lender.

24.17 No Waiver or Surrender. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Site and no agreement to accept a surrender of the Site shall be valid unless it is in writing and signed by the Landlord.

24.18 Memorandum of Lease. The Parties hereto agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’s interest hereunder, including that the Excluded Area is hereby released unto Landlord free and clear from any and all leases and amendments including the PL Ground Lease and CLV Ground Lease; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease.

 

37


25. Termination of Assignment, Automatic Amendment of Ground Lease and Reversion to Original Ground Lease

25.1 Not later than March 19, 2025 and subject to Tenant’s satisfaction of the conditions set forth below in Section 25.2, if Tenant reasonably determines that, on the basis of its environmental site preparation work, there is a material cost, risk or expense associated with the environmental conditions of the Site that would impede the construction, financing or operation of an LNG export project on the Site (the “Project”), Tenant shall be permitted, on not less than sixty (60) days’ prior written notice, to provide notice in the form attached hereto as Exhibit 6 (“Notice of Assignment and Amendment of Lease”) to Landlord that the Assignment is rendered null and void ab initio and Landlord hereby agrees that all terms and conditions of this CLV Ground Lease are thereby automatically amended in full to be the terms and conditions of the PL Ground Lease and assigned to Port Louisiana, Inc., all without any further action by Tenant. In addition, upon delivery of the Notice of Assignment and Amendment of Lease and subject to Tenant’s compliance with the conditions set forth below in Section 25.2, Tenant and Landlord hereby agree that the executed forms in Exhibit 7 and Exhibit 8 shall be recorded in the official conveyance records of Cameron Parish, Louisiana.

25.2 Tenant’s right to terminate its obligations under the Amended and Restated Lease shall be conditioned upon Tenant satisfying the following:

(a) Tenant has not created or permitted to exist any liens, security interests or mortgages in connection with the Site.

(b) Tenant shall not be in material breach of this Ground Lease;

(c) Tenant has maintained the Ground Lease, and the Ground Lease remains in full force and effect in accordance with its terms and has not been modified, changed, or amended, either in writing or orally;

(d) the Assignment and Ground Lease shall constitute the entire agreement between Landlord and Tenant with respect to the Site; and

(e) Tenant has not assigned, transferred or encumbered any of its rights under the Ground Lease.

[Remainder of page left intentionally blank; signatures on following pages]

 

38


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

      LANDLORD:
 

/s/ Kathryn Matte

     
  WITNESS     J.A. DAVIS PROPERTIES, LLC
      By:  

/s/ E. Scott Henry

 

/s/ Beth A. Hinten

    Name: E. Scott Henry
  WITNESS     Title: Manager

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Calcasieu and State of Louisiana, personally came and appeared E. Scott Henry, who, after being sworn by me, did execute this agreement on the 18th day of September, 2023 at Lake Charles, State of Louisiana.

 

 

/s/ Dallas Kingham

 
  NOTARY PUBLIC  

 

      TENANT:
 

/s/ Witness signature

     
  WITNESS     CAMERON LAND VENTURES, LLC
      By:  

/s/ Keith Larson

 

/s/ Witness signature

    Name: Keith Larson
  WITNESS     Title: Secretary

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 20th day of September, 2023 at Arlington, State of Virginia.

 

 

/s/ Michael Eliezer Millan

 
  NOTARY PUBLIC  

 

1


LIST OF EXHIBITS

 

Exhibit 1

Legal Description of the Site

 

Exhibit 2

Site Survey

 

Exhibit 3

Tenant’s Resolution

 

Exhibit 4

Landlord’s Resolution

 

Exhibit 5

Form of Non-Disturbance Agreement

 

Exhibit 6

Notice of Assignment and Amendment of Lease

 

Exhibit 7

Amendment to Ground Lease Agreement

 

Exhibit 8

Assignment of Ground Lease Agreement and Consent to Assignment

 

Exhibit 9

Excluded Area

 

40


EXHIBIT 1

LEGAL DESCRIPTION OF THE SITE

PARCEL A

COMMENCING AT THE NORTHEAST CORNER OF THE NORTHEAST QUARTER OF THE NORTHEAST QUARTER OF SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°53’27”W., A DISTANCE OF 641.64 FEET ALONG THE EAST LINE OF TOWNSHIP 14 SOUTH, RANGE 10 WEST TO A POINT; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE AND BEING THE POINT OF BEGINNING; THENCE S.00°53’27”W., A DISTANCE OF 4,637.88 FEET ALONG THE EAST LINE OF SAID TOWNSHIP TO A POINT; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE AND BEING THE SOUTHEAST CORNER OF THE SOUTHEAST QUARTER OF THE SOUTHEAST QUARTER OF SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST; THENCE S.00°53’27”W., A DISTANCE OF 2,152.32 FEET ALONG THE EAST LINE OF SAID SECTION 25 TO THE INTERSECTION OF THE EAST LINE OF SAID SECTION 25 AND THE NORTH RIGHT-OF-WAY LINE OF STATE HIGHWAY NO. 27/82 BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.74°46’40”W., A DISTANCE OF 858.86 FEET ALONG SAID STATE RIGHT-OF-WAY LINE TO A POINT OF CURVATURE BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE ALONG A CURVE TO THE RIGHT A DISTANCE OF 242.57 FEET ALONG SAID STATE RIGHT-OF-WAY LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 610.00 FEET AND A CENTRAL ANGLE OF 22°47’01”; THENCE N.51°59’39”W., A DISTANCE OF 114.49 FEET ALONG SAID STATE RIGHT-OF-WAY LINE TO A POINT OF CURVATURE BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE ALONG A CURVE TO THE LEFT A DISTANCE OF 231.86 FEET ALONG SAID STATE RIGHT-OF-WAY LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 690.00 FEET AND A CENTRAL ANGLE OF 19°15’12”; THENCE N.71°14’51”W., A DISTANCE OF 117.03 FEET ALONG SAID STATE RIGHT-OF-WAY LINE TO THE EAST LINE OF ZAPATA PROTEIN INC PROPERTY BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°49’45”E., A DISTANCE OF 217.72 FEET TO THE NORTHEAST CORNER OF THE ZAPATA PROTEIN INC PROPERTY BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.75°34’34”W., A DISTANCE OF 1,199.35 FEET TO THE NORTHWEST CORNER OF THE ZAPATA PROTEIN INC PROPERTY BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°49’45”W., A DISTANCE OF 122.58 FEET TO THE INTERSECTION OF THE WEST LINE OF THE ZAPATA PROTEIN INC PROPERTY AND THE NORTH RIGHT-OF-WAY LINE OF STATE HIGHWAY NO. 27/82 BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.71°14’51”W. A DISTANCE OF 26.51 FEET ALONG SAID STATE RIGHT-OF-WAY LINE

 

41


TO A POINT OF CURVATURE BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE ALONG A CURVE TO THE RIGHT A DISTANCE OF 619.15 FEET ALONG SAID STATE RIGHT-OF-WAY LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 980.00 FEET AND A CENTRAL ANGLE OF 36°11’55”; THENCE N.35°02’56”W., A DISTANCE OF 85.92 FEET ALONG SAID STATE RIGHT-OF-WAY LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.32°02’1l”W. A DISTANCE OF 190.27 FEET ALONG SAID STATE RIGHT-OF-WAY LINE TO A NON TANGENT POINT OF CURVATURE BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE ALONG A CURVE TO THE LEFT A DISTANCE OF 118.79 FEET ALONG SAID STATE RIGHT-OF-WAY LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; SAID NON TANGENT CURVE HAVING A RADIUS OF 686.62 FEET, A CENTRAL ANGLE OF 09°54’45”, AND CHORD OF N.39°5’2”W, 118.64 FEET; THENCE N.35°02’56”W., A DISTANCE OF 60.03 FEET ALONG SAID STATE RIGHT-OF-WAY LINE TO A NON TANGENT POINT OF CURVATURE BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE ALONG A CURVE TO THE LEFT A DISTANCE OF 187.64 FEET ALONG SAID STATE RIGHT-OF-WAY LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; SAID NON TANGENT CURVE HAVING A RADIUS OF 675.00 FEET, A CENTRAL ANGLE OF 15°54’38”, AND CHORD OF N.42°47’46”W, 187.03 FEET; THENCE N.00° 19’ 19”W., A DISTANCE OF 1,562.37 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°30’39”E., A DISTANCE OF 193.47 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE’; THENCE N.00°21’07”W., A DISTANCE OF 581.14 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°45’19”W., A DISTANCE OF 393.14 FEET TO A POINT ALONG THE EAST RIGHT-OF-WAY LINE OF WAKEFIELD ROAD BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°19’19”W., A DISTANCE OF 285.27 FEET ALONG SAID PARISH RIGHT-OF-WAY LINE TO A POINT OF CURVATURE BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE ALONG A CURVE TO THE RIGHT A DISTANCE OF 114.28 FEET ALONG SAID PARISH RIGHT-OF-WAY LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 371.03 FEET AND A CENTRAL ANGLE OF 17°38’49”; THENCE N.81°20’01”W., A DISTANCE OF 579.69 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 149.95 FEET S.81°20’01”E. OF TRUE POSITION; THENCE N.00°19’41”W., A DISTANCE OF 246.24 FEET TO A POINT; THENCE N.13° 14’5 I ”E., A DISTANCE OF 62.25 FEET TO A POINT; THENCE N.l4°19’23”W., A DISTANCE OF 199.67 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 55.01 FEET S.89°52’09”E. OF TRUE POSITION; THENCE S.89°52’09”E., A DISTANCE OF 669.61 FEET TO A POINT ON THE EAST RIGHT-OF-WAY LINE OF WAKEFIELD ROAD BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.18°03’17”W., A DISTANCE OF 564.83 FEET ALONG SAID PARISH RIGHT-OF-WAY LINE TO A POINT OF CURVATURE BEING MARKED BY A FOUND ONE AND ONE QUARTER

 

42


INCH DIAMETER IRON PIPE; THENCE ALONG A CURVE TO THE RIGHT A DISTANCE OF 233.78 FEET ALONG SAID PARISH RIGHT-OF-WAY LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 1, 168.16 FEET AND A CENTRAL ANGLE OF 11°27’58”; THENCE N.06°35’19”W., A DISTANCE OF 322.14 FEET ALONG SAID PARISH RIGHT-OF-WAY LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.85°50’55”E., A DISTANCE OF 626.73 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.06°35’19”W., A DISTANCE OF 417.40 FEET TO A POINT ON THE SOUTH RIGHT-OF-WAY LINE OF WAKEFIELD ROAD NO. 2 BEING MARKED A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.85°50’55”E., A DISTANCE OF 1,407.51 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.84°38’45”E., A DISTANCE OF 1,630.03 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.32°28’50”W., A DISTANCE OF 1,698.51 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.57°31’12”E., A DISTANCE OF 90.00 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 35.79 FEET S.32°34’07”E. OF TRUE POSITION; THENCE S.32°28’50”E., A DISTANCE OF 1,744.61 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.84°38’45”E., A DISTANCE OF 309.58 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 21,822,333.97 SQUARE FEET OR 500.9719 ACRES, IS SITUATED IN SECTIONS 24, 25 & 36 TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “A” ON THE HERE TO ATTACHED PLAT OF SURVEY PERFORMED BY LONNIE G. HARPER & ASSOCIATES, INC. DATED SEPTEMBER 31, 2022.

PARCEL Q

COMMENCING AT THE NORTHEAST CORNER OF THE NORTHEAST QUARTER OF THE NORTHEAST QUARTER OF SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°53’27”W., A DISTANCE OF 641.64 FEET TO A POINT; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE AND BEING THE POINT OF BEGINNING; THENCE S.84°38’45”W., A DISTANCE OF 309.58 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.32°28’50”W., A DISTANCE OF 1,744.61 FEET TO A POINT ALONG THE SOUTH RIGHT OF WAY LINE OF WAKEFIELD ROAD BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 35.79’ S.32°28’50”E. OF TRUE POSITION; THENCE S.57°31’32”W., A DISTANCE OF 62.60 FEET ALONG THE SOUTH RIGHT OF WAY LINE OF WAKEFIELD ROAD TO A POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE N.00°56’56”E., A DISTANCE OF 240.58 FEET TO THE

 

43


NORTHWEST CORNER OF LOT NO. 9 OF THE HENRY CLARK SURVEY, PERFORMED BY PHILIP WHITAKER, DATED AUGUST 15, 1978; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE S.88°47’45”E., A DISTANCE OF 1,319.45 FEET ALONG THE NORTH LINE OF SAID LOT NO. 9 TO A POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE S.88°49’16”E., A DISTANCE OF 2639.71 FEET TO A POINT; SAID POINT MARKED BY A FOUND TWO INCH DIAMETER IRON PIPE AND BEING THE NORTHEAST CORNER OF SAID LOT NO. 9; THENCE S.00°53’58”W., A DISTANCE OF 2,277.62 FEET TO A POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE N.89°19’01”W., A DISTANCE OF 2,639.37 FEET TO A POINT ALONG THE EAST LINE OF SAID SECTION 25; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE N.00°53’27”E., A DISTANCE OF 678.25 FEET ALONG THE EAST LINE OF SAID SECTION 25 TO THE POINT OF BEGINNING.

SAID PARCEL CONTAINS 7,452,388.63 SQUARE FEET OR 171.0833 ACRES, MORE OR LESS, IS SITUATED IN SECTIONS 24 & 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST AND SECTIONS 19 & 30 TOWNSHIP 14 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “Q” ON THE HERETO ATTACHED PLAT OF SURVEY PERFORMED BY LONNIE G. HARPER & ASSOCIATES, INC. DATED SEPTEMBER 31, 2022.

PARCEL R

COMMENCING AT THE NORTHEAST CORNER OF THE NORTHEAST QUARTER OF THE NORTHEAST QUARTER OF SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°53’27”W., A DISTANCE OF 641.64 FEET ALONG THE EAST LINE OF SAID SECTION 25 TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.84°38’45”W., A DISTANCE OF 410.70 FEET TO A POINT; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE AND BEING THE POINT OF BEGINNING; THENCE S.84°38’45”W., A DISTANCE OF 1,630.02 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.85°50’55”W., A DISTANCE OF 312.00 FEET TO A POINT OF CURVATURE BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; SAID POINT BEING ON THE SOUTH RIGHT OF WAY LINE OF WAKEFIELD ROAD NO. 2; THENCE ALONG A CURVE TO THE LEFT A DISTANCE OF 399.92 FEET TO A POINT OF TANGENCY BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; SAID CURVE BEING ALONG THE SOUTH RIGHT OF WAY LINE OF WAKEFIELD ROAD NO. 2, HAVING A RADIUS OF 810.00 FEET, A DEFLECTION ANGLE OF 28° 16’ 12”, AND A CHORD OF 379.09 FEET N.71°50’13”E.; THENCE N.57°33’37”E., A DISTANCE OF 1,341.84 FEET ALONG THE SOUTH RIGHT OF WAY LINE OF WAKEFIELD ROAD NO. 2 TO THE POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE S.32°28’50”E., A DISTANCE OF 793.30 FEET TO THE POINT OF BEGINNING.

 

44


SAID PARCEL CONTAINS 618,317.54 SQUARE FEET OR 14.1946 ACRES, MORE OR LESS, IS SITUATED IN SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “R” ON THE HERETO ATTACHED PLAT OF SURVEY PERFORMED BY LONNIE G. HARPER & ASSOCIATES, INC. DATED SEPTEMBER 31, 2022.

PARCELS

COMMENCING AT THE NORTHEAST CORNER OF THE NORTHEAST QUARTER OF THE NORTHEAST QUARTER OF SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°53’27”W., A DISTANCE OF 641.64 FEET ALONG THE EAST LINE OF SAID SECTION 25 TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.84°38’45”W., A DISTANCE OF 309.58 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.32°28’50”W., A DISTANCE OF 1,744.61 FEET TO A POINT ON THE SOUTH RIGHT OF WAY LINE OF WAKEFIELD ROAD BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 35.79’ S.32°28’50”E. OF TRUE POSITION; THENCE S.57°31’32”W., A DISTANCE OF 62.60 FEET ALONG THE SOUTH RIGHT OF WAY LINE OF WAKEFIELD ROAD TO A POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE N.00°56’57”E., A DISTANCE OF 71.51 FEET TO A POINT ON THE NORTH RIGHT OF WAY LINE OF WAKEFIELD ROAD; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE AND BEING THE POINT OF BEGINNING; THENCE S.57°35’40”W., A DISTANCE OF 1,637.16 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT BEING MARKED BY A SET PK NAIL IN TRUE POSITION AND A SET ONE INCH DIAMETER IRON PIPE, OFFSET 14.99’ N.22° 14’ 53”W. OF TRUE POSITION; THENCE S.76°52’23”W., A DISTANCE OF 815.09 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT BEING MARKED BY A FOUND FOUR INCH DIAMETER TRANSITE PIPE; THENCE S.73°26’59”W., A DISTANCE OF 681.13 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE N.06°35’19”W., A DISTANCE OF 177.71 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.83°24’41”W., A DISTANCE OF 60.00 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.06°35’19”W., A DISTANCE OF 139.19 FEET TO A POINT ON THE MEAN LOW WATER LINE OF THE LEFT DESCENDING BANK LINE OF THE EAST FORK OF THE CALCASIEU RIVER; SAID POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 78.46’ S.06°35’ 19”E. OF TRUE POSITION; THENCE NORTHEASTERLY A DISTANCE OF 3,427.53 FEET ALONG SAID MEAN LOW WATER LINE TO A POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE, OFFSET 25.04’ S.00°56’56”W. OF TRUE POSITION; THENCE S.00°56’56”W., A DISTANCE OF 439.75 FEET TO THE POINT OF BEGINNING.

 

45


SAID PARCEL CONTAINS 1,358,858.57 SQUARE FEET OR 31.1951 ACRES, MORE OR LESS, IS SITUATED IN SECTIONS 24 & 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “S” ON THE HERETO ATTACHED PLAT OF SURVEY PERFORMED BY LONNIE G. HARPER & ASSOCIATES, INC. DATED SEPTEMBER 31, 2022.

PARCEL T

COMMENCING AT THE NORTHEAST CORNER OF THE NORTHEAST QUARTER OF THE NORTHEAST QUARTER OF SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°53’27”W., A DISTANCE OF 641.64 FEET ALONG THE EAST LINE OF SAID SECTION 25 TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.84°38’45”W., A DISTANCE OF 309.58 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.32°28’50”W., A DISTANCE OF 1,744.61 FEET TO A POINT ON THE SOUTH RIGHT OF WAY LINE OF WAKEFIELD ROAD BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 35.79’ S.32°28’50”E. OF TRUE POSITION; THENCE S.57°31’32”W., A DISTANCE OF 90.00 FEET ALONG THE SOUTH RIGHT OF WAY LINE OF WAKEFIELD ROAD TO A POINT; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE AND BEING THE POINT OF BEGINNING; THENCE S.32°28’50”E., A DISTANCE OF 836.26 FEET TO A POINT ON THE NORTH RIGHT OF WAY LINE OF WAKEFIELD ROAD NO. 2; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE S.57°38’30”W., A DISTANCE OF 1,345.29 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT OF CURVATURE BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE ALONG SAID RIGHT OF WAY LINE AND A CURVE TO THE RIGHT A DISTANCE OF 364.88 FEET TO A POINT OF TANGENCY BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 741.56 FEET, A DEFLECTION ANGLE OF 28°13’20”, AND A CHORD OF 343.01 FEET S.71°44’15”W.; THENCE S.85°51 ‘49”W., A DISTANCE OF 1,722.33 FEET ALONG SAID RIGHT OF WAY LINE TO THE INTERSECTION OF THE NORTH RIGHT OF WAY LINE OF WAKEFIELD ROAD NO. 2 AND THE EAST RIGHT OF WAY LINE OF WAKEFIELD ROAD; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE N.06°35’24”W., A DISTANCE OF 435.25 FEET ALONG SAID RIGHT OF WAY LINE TO THE INTERSECTION OF THE EAST RIGHT OF WAY LINE AND THE SOUTH RIGHT OF WAY LINE OF WAKEFIELD ROAD; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE N.73°45’25”E., A DISTANCE OF 689.51 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE N.76° 19’55”E., A DISTANCE OF 831.67 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE N.57°39’03”E., A DISTANCE OF 1,571.58 FEET ALONG SAID RIGHT OF WAY LINE TO THE POINT OF BEGINNING.

 

46


SAID PARCEL CONTAINS 2,319,555.52 SQUARE FEET OR 53.2497 ACRES, MORE OR LESS, IS SITUATED IN SECTIONS 24 & 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “T” ON THE HERETO ATTACHED PLAT OF SURVEY PERFORMED BY LONNIE G. HARPER & ASSOCIATES, INC. DATED SEPTEMBER 31, 2022.

PARCEL U

COMMENCING AT THE NORTHEAST CORNER OF THE NORTHEAST QUARTER OF THE NORTHEAST QUARTER OF SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°53’27”W., A DISTANCE OF 641.64 FEET ALONG THE EAST LINE OF SAID SECTION 25 TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.84°38’45”W., A DISTANCE OF 410.70 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.84°38’44”W., A DISTANCE OF 1,630.02 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.85°50’54”W., A DISTANCE OF 312.00 FEET TO A POINT ON THE SOUTH LINE OF WAKEFIELD ROAD NO. 2; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE S.85°50’54”W., A DISTANCE OF 1,095.51 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE AND BEING THE POINT OF BEGINNING; THENCE S.06°35’ 13”E., A DISTANCE OF 417.39 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.85°50’53”W., A DISTANCE OF 626.72 FEET TO A POINT ON THE EAST RIGHT OF WAY LINE OF WAKEFIELD ROAD; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.06°35’19”W., A DISTANCE OF 417.40 FEET ALONG SAID RIGHT OF WAY LINE TO THE INTERSECTION OF THE EAST LINE OF WAKEFIELD ROAD AND THE SOUTH RIGHT OF WAY LINE OF WAKEFIELD ROAD NO. 2; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE N.85°50’55”E., A DISTANCE OF 626.73 FEET ALONG SAID RIGHT OF WAY LINE TO THE POINT OF BEGINNING.

SAID PARCEL CONTAINS 261,355.97 SQUARE FEET OR 5.9999 ACRES, MORE OR LESS, IS SITUATED IN SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “U” ON THE HERETO ATTACHED PLAT OF SURVEY PERFORMED BY LONNIE G. HARPER & ASSOCIATES, INC. DATED SEPTEMBER 31, 2022.

 

47


PARCEL V

COMMENCING AT THE NORTHEAST CORNER OF THE NORTHEAST QUARTER OF THE NORTHEAST QUARTER OF SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.88°49’ 11”W., A DISTANCE OF 4,255.25 FEET ALONG THE NORTH LINE OF SAID SECTION 25 TO A POINT; THENCE S.06°35’19”E., A DISTANCE OF 198.40 FEET TO A POINT ON THE MEAN LOW WATER LINE OF THE LEFT DESCENDING BANK LINE OF THE CALCASIEU RIVER SHIP CHANNEL; SAID POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 78.46’ S.06°35’ 19”E. OF TRUE POSITION AND BEING THE POINT OF BEGINNING; THENCE S.06°35’19”E., A DISTANCE OF 121.04 FEET TO A POINT ON THE WEST RIGHT OF WAY LINE OF WAKEFIELD ROAD; SAID POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.06°35’19”E., A DISTANCE OF 1,482.87 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT OF CURVATURE BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE ALONG SAID RIGHT OF WAY LINE AND A CURVE TO THE LEFT A DISTANCE OF 245.78 FEET TO A POINT OF TANGENCY BEING MARKED BY A FOUND THREE QUARTER INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 1,230.78 FEET, A DEFLECTION ANGLE OF 11°26’30”, AND A CHORD OF 245.37 FEET S. I 2° 19’ 18”E.; THENCE S. 18°02’33”E., A DISTANCE OF 545.19 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.89°52’09”W., A DISTANCE OF 580.95 FEET TO A POINT ALONG THE MEAN LOW WATERLINE OF THE LEFT DESCENDING BANK LINE OF THE CALCASIEU RIVER SHIP CHANNEL; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 29.82’ S.89°51 ‘32”E. OF TRUE POSITION; THENCE NORTHERLY A DISTANCE OF 2,655.10 FEET ALONG SAID MEAN LOW WATER LINE TO THE POINT OF BEGINNING.

SAID PARCEL CONTAINS 842,355.09 SQUARE FEET OR 19.3378 ACRES, MORE OR LESS, IS SITUATED IN SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “V” ON THE HERETO ATTACHED PLAT OF SURVEY PERFORMED BY LONNIE G. HARPER & ASSOCIATES, INC. DATED SEPTEMBER 31, 2022.

 

48


PARCEL W

COMMENCING AT THE NORTHEAST CORNER OF THE NORTHEAST QUARTER OF THE NORTHEAST QUARTER OF SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°53’27”W., A DISTANCE OF 5,279.52 FEET ALONG THE EAST LINE OF SAID SECTION TO THE SOUTHEAST CORNER OF THE SOUTHEAST QUARTER OF THE SOUTHEAST QUARTER OF SAID SECTION 25; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.89°08’28”W., A DISTANCE OF 3,804.67 FEET ALONG THE SOUTH LINE OF SAID SECTION TO THE INTERSECTION OF THE WEST RIGHT OF WAY LINE OF WAKEFIELD ROAD AND THE SOUTH LINE OF SAID SECTION 25; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE AND BEING THE POINT OF BEGINNING; THENCE S.00°19’08”E., A DISTANCE OF 247.86 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT OF CURVATURE BEING MARKED BY A FOUND LOUISIANA DOTD RIGHT OF WAY MARKER; THENCE ALONG THE NORTH RIGHT OF WAY LINE OF LOUISIANA STATE HIGHWAY NO. 27/82 AND A CURVE TO THE LEFT A DISTANCE OF 159.96 FEET TO A POINT OF TANGENCY BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 865.16 FEET, A DEFLECTION ANGLE OF 10°35’37”, AND A CHORD OF 159.96 FEET N.82°30’07”W.; THENCE N.70°50’58”W., A DISTANCE OF 293.50 FEET ALONG SAID RIGHT OF WAY LINE TO THE MEAN LOW WATER LINE ALONG THE LEFT DESCENDING BANK LINE OF THE CALCASIEU RIVER SHIP CHANNEL; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; THENCE NORTHERLY A DISTANCE OF 2,443.60 FEET ALONG SAID MEAN LOW WATER LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.81°18°13”E., A DISTANCE OF 369.06 FEET TO A POINT ON THE WEST RIGHT OF WAY LINE OF WAKEFIELD ROAD; SAID POINT OF CURVATURE BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 11.20’ N.81° 18’45”W. OF TRUE POSITION; THENCE ALONG SAID RIGHT OF WAY AND A CURVE TO THE LEFT A DISTANCE OF 123.61 FEET TO A POINT OF TANGENCY BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 431.07 FEET, A DEFLECTION ANGLE OF 16°25’49”, AND A CHORD OF 123.21 FEET S.7°53’44”W.; THENCE S.00° 19’08”E., A DISTANCE OF 2,043.73 FEET ALONG SAID RIGHT OF WAY LINE TO THE POINT OF BEGINNING.

SAID PARCEL CONTAINS 1,080,665.12 SQUARE FEET OR 24.8087 ACRES, MORE OR LESS, IS SITUATED IN SECTIONS 25 & 36, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “W” ON THE HERETO ATTACHED PLAT OF SURVEY PERFORMED BY LONNIE G. HARPER & ASSOCIATES, INC. DATED SEPTEMBER 31, 2022.

PARCEL X

COMMENCING AT THE NORTHEAST CORNER OF THE NORTHEAST QUARTER OF THE NORTHEAST QUARTER OF SECTION 25, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°53’27”W., A DISTANCE OF 5,279.52 FEET ALONG THE EAST LINE OF SAID SECTION TO A POINT; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE

 

49


AND BEING THE SOUTHEAST CORNER OF THE SOUTHEAST QUARTER OF THE SOUTHEAST QUARTER OF SAID SECTION 25; THENCE N.89°08’28”W., A DISTANCE OF 3,544.61 FEET ALONG SAID SECTION LINE TO A POINT; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE AND BEING THE POINT OF BEGINNING; THENCE S.00° 19’ 19”E., A DISTANCE OF 377.29 FEET TO A POINT OF CURVATURE BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; SAID POINT BEING ON THE NORTH RIGHT OF WAY LINE OF LOUISIANA STATE HIGHWAY NO. 27/82; THENCE ALONG SAID RIGHT OF WAY AND A CURVE TO THE LEFT A DISTANCE OF 233.17 FEET TO THE INTERSECTION OF SAID RIGHT OF WAY LINE AND THE EAST RIGHT OF WAY LINE OF WAKEFIELD ROAD; SAID POINT BEING MARKED BY A SET ONE INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 625.08 FEET, A DEFLECTION ANGLE OF 21°22’22”, AND A CHORD OF 200.77 FEET N.60°00’27”W.; THENCE N.00°19’19”W., A DISTANCE OF 2,024.49 FEET ALONG SAID RIGHT OF WAY LINE TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.89°50’48”E., A DISTANCE OF 392.98 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°22’04”E., A DISTANCE OF 580.51 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.89°30’39”W., A DISTANCE OF 193.47 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°19’19”E., A DISTANCE OF 1, 185.08 FEET TO THE POINT OF BEGINNING.

SAID PARCEL CONTAINS 528,485.94 SQUARE FEET OR 12.1324 ACRES, MORE OR LESS, IS SITUATED IN SECTIONS 25 & 36, TOWNSHIP 14 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “X” ON THE HERETO ATTACHED PLAT OF SURVEY PERFORMED BY LONNIE G. HARPER & ASSOCIATES, INC. DATED SEPTEMBER 31, 2022.

 

50


EXHIBIT 2

SURVEY MAP OF SITE

[Omitted]


EXHIBIT 3

TENANT’S RESOLUTION

[Omitted]


EXHIBIT 4

LANDLORD’S RESOLUTION

[Omitted]


EXHIBIT 5

FORM OF NON-DISTURBANCE AGREEMENT

[Omitted]


EXHIBIT 6

FORM OF NOTICE OF ASSIGNMENT

AND AUTOMATIC AMENDMENT OF GROUND LEASE

[Omitted]


EXHIBIT 7

FORM OF AMENDMENT TO GROUND LEASE AGREEMENT

[Omitted]


EXHIBIT 8

FORM OF ASSIGNMENT OF

GROUND LEASE AGREEMENT AND CONSENT TO ASSIGNMENT

[Omitted]

Exhibit 10.57

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

STATE OF LOUISIANA

PARISH OF CAMERON

GROUND LEASE AGREEMENT

(184 Acres)

This GROUND LEASE AGREEMENT (this “Ground Lease”) is executed and effective as of October 12, 2023 (the “Ground Lease Commencement Date”), by and between Venture Global CP2 LNG, LLC, a Delaware limited liability company (the “Tenant”), and Wilma Davis Bride Family, LLC, a Louisiana limited liability company (the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Cameron Parish, Louisiana, which comprises approximately one hundred eighty-four (184) acres; and

WHEREAS, the Tenant wishes to lease land owned by the Landlord for the construction, development and operation of a natural gas liquefaction facility and liquefied natural gas (“LNG”) export terminal (the “Facilities”) and other uses permitted by this Ground Lease; and

WHEREAS, in accordance with the above, the Tenant has executed this Ground Lease and offers fair value to the Landlord as cause and consideration for this Ground Lease.

NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this Ground Lease, and the Parties herein covenant and agree as follows:

1. Definitions.

As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

“Adjustment Period” has the meaning set forth in Section 4.l(c).

“Affiliate” means any Person controlled by, controlling or under common control with the Landlord or the Tenant, as applicable. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of thirty percent (30%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.

“Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Site, the Landlord, or the Tenant in respect of the subject matter in question.


“Bankruptcy Proceeding” has the meaning set forth in Section 23.10.

“Bona Fide Offer” has the meaning set forth in Section 14.3.

“Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in the State of New York are authorized or required by law to close.

“Consumer Price Index” has the meaning set forth in Section 4.2.

“Corps” has the meaning set forth in Section 8.3(a).

“Corrective Measures” has the meaning set forth in Section 9.4(b).

“CPI Adjustment” has the meaning set forth in Section 4.1.

“CPI Disagreement Notice” has the meaning set forth in Section 4.2.

“CPI Notice” has the meaning set forth in Section 4.2.

“CPI Percentage Increase” has the meaning set forth in Section 4.2.

“Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Law relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

“Estimated CPI Percentage Increase” has the meaning set forth in Section 4.2.

“Event of Default” has the meaning set forth in Section 15.1.

“Extended Term” has the meaning set forth in Section 3.2.

“Facilities” has the meaning set forth in the Recitals hereof.

“Facility Contractors” means, collectively, the Persons engaged by the Tenant to construct the Facilities and/or develop the Facilities, the Site and/or the Improvements.

“Facility Contracts” means, collectively, the contracts entered into by the Tenant in connection with the design, construction, equipment procurement, operation and maintenance of the Facilities, the Site and/or the Improvements.

 

2


“Fair Market Value” means the value determined pursuant to the process set forth in Section 14.5.

“Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Facilities, the Improvements, the Site, or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders.

“First Appraiser” has the meaning set forth in Section 14.5.

“Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include, but not be limited to, the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, droughts, floods, washouts, explosions, breakage or accident or necessity of repairs to machinery or equipment or lines of pipe; (ii) weather related events affecting an entire geographic region; (iii) acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, terrorism, discovery of burial grounds or human remains or legally protected artifacts, insurrections or wars; (iv) the failure or interruption of performance by the Tenant’s engineering, procurement and construction contractor or any subcontractors of such contractor to the extent caused by an event of Force Majeure under this Ground Lease; (v) the failure or interruption of performance by the Tenant’s suppliers by reason of such supplier’s valid declaration of an event that would constitute an event of force majeure under the Tenant’s contract with such supplier; (vi) governmental actions such as necessity for compliance with any court order, law, statute, ordinance, regulation, or policy having the effect of law promulgated by a Governmental Authority having jurisdiction, or that restrict the Tenant’s ability to reasonably construct and/or operate the Facilities or the Improvements or any delay in issuance or effectiveness of any Governmental Approval that has been properly applied for by the Tenant that is required to construct and/or operate the Facilities or the Improvements.

“Governmental Approval” means any authorization, waiver, consent, approval, license, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority.

“Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

“Ground Lease” has the meaning set forth in the Preamble hereof.

“Ground Lease Commencement Date” has the meaning set forth in the Preamble hereof.

 

3


“Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

“Hazardous Substances Law” means any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including, but not limited to, the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent it relates to the handling of and exposure to hazardous or toxic materials or similar substances.

“Improvements” means any and all improvements made by Tenant, in its sole discretion, to the Site, including but not limited to, improvements relating to the loading, unloading, handling, treatment, processing, producing, transporting, distributing, selling, metering and/or storing of (i) natural gas, natural gas liquids, and other natural gas products, derivatives and by-products and (ii) other petroleum and hydrocarbon liquids, gases, products, derivatives and by-products, including but not limited to (A) the importation, regasification, production, exportation, liquefaction, refinement, enhancement, other treatment and transportation (including by ship, pipeline, truck or rail) of LNG, and LNG by-products and additives and (B) the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of any improvements, component parts and other constructions, fixtures, facilities, equipment and/or appurtenances (including natural gas pipelines, natural gas liquids extraction, processing and delivery facilities, acid gas removal units, natural gas liquefaction trains, LNG regasification facilities, and other treatment facilities, cryogenic pipelines, LNG storage tanks, petroleum and other hydrocarbon liquids storage facilities, nitrogen storage and processing facilities, power generation and transmission infrastructure, marine, rail

 

4


and trucking receipt, delivery and servicing facilities (including piers, marine terminals, bulkheads, wharfs, docks, inlets, wetslips, moonpools, moorings, jetties, and loading and unloading equipment), and other utilities and facilities (including berms, open space, security fencing, control rooms, offices, warehouses, parking and yards), in each case, necessary, ancillary or desirable to the Tenant in connection with the foregoing.

“Initial Term” has the meaning set forth in Section 3.1.

“Landlord” has the meaning set forth in the Preamble hereof.

“Landlord Estoppel” has the meaning set forth in Section 23.11(a).

“Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, affiliates, invitees, agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Site and/or Landlord’s Improvements.

“Landlord’s Event of Default” has the meaning set forth in Section 16.1 16.1.

“Landlord Indemnitee” has the meaning set forth in Section 9.1.

“Landlord’s Improvements” has the meaning set forth in Section 6. 1.

“Lease Year” means a period of twelve (12) consecutive full calendar months. The first Lease Year shall begin on the Ground Lease Commencement Date. Each succeeding Lease Year shall commence upon the anniversary of the first day of the previous Lease Year.

“Leasehold Lenders” has the meaning set forth in Section 23.1.

“Leasehold Loan” has the meaning set forth in Section 23.1.

“Leasehold Mortgage” has the meaning set forth in Section 23.1.

“Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

“LNG” has the meaning set forth in the Recitals hereof.

“Minerals” has the meaning set forth in Section 8.3(b).

“New Lease” has the meaning set forth in Section 23.9(a).

“Non-Disturbance Agreement” has the meaning set forth in Section 23.11(c).

 

5


“Option Agreement” means the Real Estate Lease Option Agreement between Landlord and Tenant (as successor in interest to Cameron Land Ventures, LLC), dated as of August 14, 2019.

“Party” or “Parties” has the meaning set forth in the Preamble hereof.

“Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

“Property Taxes” means all real (immovable) and personal (movable) property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

“Removal Period” means the period of time that is required by Tenant to remove any and all of Tenant’s Property, including the Facilities and/or Improvements, from the Site in accordance with Section 7.1.

“Rent” has the meaning set forth in Section 4.1.

“Second Appraiser” has the meaning set forth in Section 14.5.

“Site” means the real (immovable) property of approximately one hundred eighty-four ( 184) acres described in the legal description set forth in Exhibit 1, and illustrated by the Survey Map attached as Exhibit 2, upon which the Facilities and any Improvements will be located and which real (immovable) property is owned by the Landlord.

“Surface Waiver” has the meaning set forth in Section 8.3(b).

“Survey Map” means the ALTA survey of the Site, dated June 12, 2019, by Lonnie G. Harper & Associates, Inc., attached as Exhibit 2.

“Tenant” has the meaning set forth in the Preamble hereof.

“Tenant Estoppel” has the meaning set forth in Section 23.11(b).

“Tenant Indemnitee” has the meaning set forth in Section 9.3.

“Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Site by or on behalf of the Tenant, including the Facilities and any Improvements.

“Third Appraiser” has the meaning set forth in Section 14.5.

 

6


2. Ground Lease Premises.

2.1 Date. The date of this Ground Lease is the Ground Lease Commencement Date.

2.2 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of the rents and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does lease to the Tenant and the Tenant hereby leases from the Landlord, the Site and Landlord’s Improvements. Without limiting Landlord’s obligations under Section 8.2(b), Landlord specifically reserves all mineral rights in any way related to the Site for the exploration, development and production of all oil, gas and other mineral lying below the surface of the Site, provided only that Landlord will not exercise or grant any surface rights other than those that may be exercised without interfering with the Tenant’s activities and uses of the Site.

2.3 Servitudes. In addition, the Landlord shall without cost to the Tenant, grant from time to time to the Tenant and others designated by the Tenant any easements, servitudes, and rights of way for access and electricity, communications, gas, water, sewer and other utility lines, products and materials from and to the Site over land and waterways sufficient to permit the Tenant to access adjacent lands owned by the Landlord and to accomplish its purposes in connection with the Improvements or the Facilities.

3. Term

3.1 Initial Term. The initial term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on the thirtieth (30th) anniversary of the last day of the month immediately preceding the Ground Lease Commencement Date (the “Initial Term”).

3.2 Extensions.

(a) In consideration of and conditioned upon there being no uncured Event of Default on the part of the Tenant at the time an option is exercised, the Landlord hereby grants unto the Tenant the option to lease the Site for four (4) additional ten (10) year terms. If the extension option is exercised in accordance with Section 3.2(b), the first of said additional terms shall commence upon the expiration of the Initial Term and extend for a period of ten (10) years and each of said additional terms shall commence upon the expiration of the then-current additional term and extend for a period of ten (10) years. Each of such additional terms is referred to herein as an “Extended Term”.

(b) The option to extend this Ground Lease of the Site as set forth in Section 3.2(a) must be exercised in each case, if at all, by written notice from the Tenant to the Landlord on or before the date that is three (3) months prior to the expiration of the Initial Term or the then-current Extended Term, as applicable. The failure of the Tenant to timely exercise the first Extended Term or any subsequent Extended Term shall automatically terminate the right of the Tenant to exercise its option to lease the Site in any subsequent Extended Term.

 

7


(c) All the terms and conditions of this Ground Lease shall be applicable to any Extended Term and the Rent payable by the Tenant for any Extended Term shall be in accordance with the provisions set forth in Article 4.

4.1 Rent. Commencing upon the Ground Lease Commencement Date, the initial rent for the Site (“Rent”) shall be [***] per annum, payable in equal installments of [***] per month, adjusted upward every five (5) years thereafter during the Initial Term and during any Extended Term by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment during any Adjustment Period (as defined below) of greater than [***]. Each five (5) year period following the Ground Lease Commencement Date shall be defined herein as an “Adjustment Period.” Any upward adjustment based on a CPI Percentage Increase (as defined below) to any payment under this Ground Lease shall hereinafter be referred to as a “CPI Adjustment.” Such Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month, provided however, that: (a) the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; and (b) the first payment of Rent due upon the commencement of any new Adjustment Period will be owed and paid one month after the commencement of that Adjustment Period and shall reflect the Estimated CPI Percentage Increase, if any.

4.2 CPI Adjustment. If CPI Percentage Increase (as defined below) is more than [***] for the relevant Adjustment Period, then the Rent payable during that Adjustment Period shall be adjusted upward by a percentage equal to the CPI Percentage Increase ( as defined below) applicable to such Adjustment Period, but not to exceed an adjustment during any Adjustment Period of greater than [***]. The term “Consumer Price Index”_shall mean the unadjusted Consumer Price Index for All Urban Workers, U.S. City Average, All Items, 1982-84=100, calculated and published by the United States Department of Labor, Bureau of Labor Statistics. The “CPI Percentage Increase” shall mean, with respect to any Adjustment Period, [***]. For the avoidance of doubt, no CPI Adjustment shall be made to any payment due under this Ground Lease for any Adjustment Period if the result of such CPI Adjustment would be to (a) reduce the amount of such payment to an amount that is less than the amount of such payment due for the immediately preceding Adjustment Period or (b) to raise the amount of such payment to an amount that is greater than [***]. For illustrative purposes only, [***].

 

8


The CPI Percentage Increase for any Adjustment Period shall be calculated by the Tenant (the “Estimated CPI Percentage Increase”), and the Tenant shall deliver written notice (“CPI Notice”) to the Landlord describing such calculation in reasonable detail no later than thirty (30) days after the commencement of any Adjustment Period. If the Landlord disagrees with the Estimated CPI Percentage Increase, then the Landlord shall deliver to the Tenant written notice (“CPI Disagreement Notice”), describing the basis for such disagreement in reasonable detail, not later than thirty (30) days after delivery to it of the CPI Notice, and the Parties shall thereafter promptly negotiate in good faith to agree on a final CPI Percentage Increase. If the Parties agree on a CPI Percentage Increase that exceeds the Estimated CPI Percentage Increase, then the Tenant shall include with its next following payment of Rent pursuant to Section 4.1 a true-up amount equal to the product of (a) the positive difference between the agreed CPI Percentage Increase and the Estimated CPI Percentage Increase, expressed as a percentage and (b) the division of (i) the Rent previously paid during such Adjustment Period by (ii) the Estimated CPI Percentage Increase plus one hundred percent (100%). If the Landlord fails to deliver a CPI Disagreement Notice within thirty (30) days after delivery of any CPI Notice to it, then the Landlord shall be conclusively deemed to have agreed with the Estimated CPI Percentage Increase set forth in such CPI Notice.

4.3 Due Date. Except as otherwise provided in this Ground Lease, all Rent payments shall be due in advance on the 1st calendar day of each month and payable by the 15th calendar day of each month during the entire term of this Ground Lease; provided, however, that the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month. If the 15th calendar day of a month falls on a weekend day or holiday, then Rent shall be payable on the following Business Day.

4.4 Place of Payment. Except as otherwise provided herein, Rent shall be payable by check at the following address - [***] - or via wire instructions as the Landlord may specify and the Tenant deem acceptable.

5. Net Lease: Taxes and Utility Expenses.

5.1 Net Lease. This Ground Lease is a net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs of every kind and nature whatsoever relating to the Site, except as expressly otherwise provided in this Ground Lease.

5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and Governmental Approval fees applicable to the Site during the term of this Ground Lease.

 

9


(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on or related to, the Improvements, but not the underlying real property comprising the Site during the term of this Ground Lease. The Landlord shall promptly provide all Property Tax bills when they become available. Upon the latter of (i) one (1) month after receipt of such Property Tax bill from the Landlord or (ii) the due date of any such Property Taxes, the Tenant shall provide the Landlord with reasonable written evidence from the Cameron Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

5.3 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost and at no cost to the Landlord, electricity, telephone, water, sewerage, gas, and other utility services to the Site; provided, however, the Landlord shall cooperate, and to the extent reasonably needed, facilitate the contracting of any easements, servitudes and/or rights of way, and grant easements, servitudes and rights of way in accordance with Section 2.3, as required by the Tenant for such utility connections and/or services.

6. Tenant and Landlord Improvements.

6.1 Landlord’s Improvements. “Landlord’s Improvements” are any and all improvements to the immovable property of the Site and any and all movable property in existence on the Site at the time of the Ground Lease Commencement Date. There are no Landlord’s Improvements.

6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install on the Site, any Improvements during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. The Tenant shall be permitted to make any changes, improvements or alterations to the Site, including, without limitation, the Facilities and any Improvements to the Site, during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws.

6.3 Governmental Approvals. The Landlord will cooperate and assist (and never oppose) the Tenant in obtaining any and all Governmental Approvals deemed necessary by the Tenant for the Facilities and all other Improvements to the Site, including with respect to Governmental Approvals from the Federal Energy Regulatory Commission and the Department of Energy. The Landlord will hereafter continue to be obligated to execute appropriate documentation to waive its right to require wetlands mitigation to be completed on the Site or other real (immovable) property owned by the Landlord, in such form as necessary to allow the Tenant to complete such wetlands mitigation at locations other than other real (immovable) property owned by the Landlord.

6.4 Tenant’s Property. The Tenant’s Property shall at all times be and remain the sole property of the Tenant.

6.5 Maintenance of Improvements.

 

10


(a) Tenant’s Obligation to Maintain. During the Initial Term or any Extended Term, as applicable, the Tenant will keep in reasonably good state of repair the Facilities, the Improvements, open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Site by the Tenant, and the Tenant will, in its sole discretion and cost, repair such property as often as may be necessary in order to keep the Facilities and the Improvements in reasonably good repair and condition, except as set forth in Section 6.5(b).

(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease, the Landlord has no obligation to maintain the Site, Improvements and/or Landlord’s Improvements (if any) during the Initial Term and/or any Extended Term. The Landlord further agrees that there will be no Landlord improvements on the Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

7. Tenant’s Surrender of Site.

7.1 Surrender at End of Ground Lease. Subject to Section 6.4 and subject and subordinate to Section 23 and the rights of any Leasehold Lender under any Leasehold Mortgage, the Tenant shall and will on the last day of the Initial Term, or if extended, on the last day of the Extended Term hereof, surrender and deliver the Site to the Landlord, in good condition as is reasonably practicable (except as provided in Section 6.5 or Section 13), excepting normal wear and tear. If this Ground Lease is terminated for any reason or upon the expiration of the Initial Term and/or Extended Term (if extended) of this Ground Lease, the Tenant shall in good faith proceed with (i) any removal of the Facilities and any and all Improvements and (ii) restoration, if any, of the Site to its condition prior to construction of the Facilities and/or Improvements. The Tenant shall have all access rights to the Site that are necessary to remove any and all of the Tenant’s Property, including the Facilities and/or Improvements. The Tenant shall also comply as required by any federal regulations of the Federal Energy Regulatory Commission or any other federal authority with respect to the Facilities on the Site.

7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date the Tenant shall assume full dominion, control and responsibility for the Site, except to the extent specifically provided herein, to the extent provided under LSA - R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real (immovable) or personal (movable) property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its officers, representatives, agents, or employees or the Landlord’s misrepresentations or its breach of or default under this Ground Lease.

 

11


7.3 Holding Over. Except for a Removal Period, if the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, and shall not constitute a renewal or extension of the term of this Ground Lease.

8. Use.

8.1 Permitted Uses: Compliance with Laws: Permits. The Tenant may use the Site for any and all uses desired by the Tenant in compliance with all Applicable Laws. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the construction, operation, and maintenance of the Facilities, the Improvements and/or for the Tenant’s use or activities on the Site. The Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Facilities, the Improvements, and the security of the Site, including, but not limited to, the timely filing, implementation, and enforcement of any security plan required by Applicable Laws. Any fine or penalty imposed by any Governmental Authority to the extent caused by the failure of the Tenant to comply with this provision, including any fine or penalty imposed upon the Landlord as owner of the Site to the extent caused by the failure of the Tenant to comply with this provision, shall be the responsibility of the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall indemnify, defend, and hold harmless the Landlord from the payment of or claim for any such fine or penalty, and the Tenant may pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord. For the avoidance of doubt, the Tenant shall not be responsible for any fine or penalty imposed by a Governmental Authority with respect to the Tenant, the Landlord or the Site to extent attributable to actions or omissions of the Landlord.

8.2 Dirt Moving Activities; Permits; Timber.

(a) The Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Site, to the Site, and from portions of the Site to other portions of the Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Site and may do so in its discretion. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Site, including without limitation, for any Improvements, reclamation of lands, erosion control, attainment of spoil, easements/servitudes and/or rights of way; provided, that all costs associated with such efforts shall be the responsibility of the Tenant. Except only as provided in Section 8.2(b). the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Site, and all other rights on and to the Site. Any activities of the Landlord and/or its lessees or assignees or any other party shall not adversely affect the Site or the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any way. Nothing herein is intended to preclude the Landlord, from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation. The Tenant may freely remove any timber which is standing or lying on the Site as the Tenant deems necessary for the Tenant’s intended use of the Site. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights below the surface of the Site.

 

12


(b) To the extent the Landlord holds any rights to oil, gas, or other minerals (“Minerals”) in the Site, the Landlord waives any and all rights of the Landlord or its lessees or assignees to use the surface of the Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the term of this Ground Lease, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means consistent with the terms and conditions of this Section 8.2(b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Facilities or interfere with the Tenant’ s operations or rights under this Ground Lease in any way.

8.3 Crossing. The Landlord shall assist the Tenant in the Tenant’ s efforts to develop, at the Tenant’ s cost, any roads and/or crossings or other Improvements across the Site and boundary lines of the Site to the adjacent land, including relocation of utilities, providing culverts for storm water drainage, and any other Improvements. The Tenant or others, excluding the Landlord, will pay the cost to relocate or modify the infrastructure for these roads and/or crossings and/or other Improvements.

9. Indemnification.

9.1 Tenant’ s General Agreement to Indemnify. The Tenant releases the Landlord, its officers, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to indemnify and defend the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, witness fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Landlord Indemnitee arising out of (i) the use or occupancy of the Site by the Tenant, its officers, representatives, agents, and employees, (ii) the construction or operation of the Facilities by the Tenant, its officers, representatives, agents, and employees, (iii) any claim arising out of the use, occupancy, construction or operation of the Site by the Tenant, its officers, representatives, agents, and employees, and (iv) activities on or about the Site by the Tenant, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, operation, maintenance, or repair of the Site, the Facilities, or the Improvements, by the Tenant, its officers, representatives, agents, and employees; provided, however, that any such claim, liability, obligation, damage or penalty arising as a result of the negligence or willful misconduct of any Landlord Indemnitee shall be excluded from this indemnity. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9 .2 and 9.4 and not this Section 9.1.

 

13


9.2 Tenant’s Environmental Indemnification. For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with all Environmental Laws applicable to the Tenant, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Tenant agrees to indemnify, defend, and hold harmless the Landlord Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorney, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth above in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Site or any violation of any Environmental Law with respect to the Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, and maintenance activities or facilities and not caused by the Landlord’s Activities or Landlord’s Improvements.

9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Site by the Landlord, its officers, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Site by the Landlord, its officers, representatives, agents, and employees, and (iii) activities on or about the Site by the Landlord, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation, damage or penalty arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope but not be limited to any and all claims or actions for wrongful death arising from the Landlord’s Activities or use of the Site, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.4 and not this Section 9.3.

9.4 Landlord’s Environmental Indemnification.

(a) For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorneys, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in

 

14


connection with, or relating to the subject matter of: (i) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances, or (ii) any actual or alleged violation of Environmental Laws, in the case of each of subclauses (i) and (ii), where the presence, discharge or release of such Hazardous Substances or violation of Environmental Law arises or occurs (1) at, on or from the Site on or prior to the Ground Lease Commencement Date or (2) at, on or from the Site or any other site as a result of or relating to the Landlord’s Activities or facilities or Landlord’s Improvements, whether before, on or after the Ground Lease Commencement Date, or (iii) the Landlord’s breach of the covenant set forth above in this Section 9.4 or (iv) any environmental condition of contamination on the Site or any violation of any Environmental Law with respect to the Site to the extent occurring after the Ground Lease Commencement Date and caused by the Landlord’s Activities or facilities.

(b) If Hazardous Substances become present or are discharged onto the Site as a result of the Landlord’s Activities or otherwise exist at the Site on or prior to the Ground Lease Commencement Date, the Tenant shall so notify the Landlord in writing as soon as practicable after the Tenant’s discovery thereof. Except with respect to Hazardous Substances that become present or are discharged onto the Site as a result of the Landlord’s Activities, such discovery and notice to the Landlord must occur within the Initial Term of this Ground Lease for the Landlord to have any obligation to perform any Corrective Measures (as hereinafter defined). Except as provided in the following sentence, upon receipt of such notice from the Tenant, the Landlord shall have a reasonable period of time to undertake, at its own expense, but subject to a limit of $5,000,000, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority (“Corrective Measures”), except that such Corrective Measures shall not unreasonably interfere with the construction, operation or maintenance of the Facilities and/or interfere the Improvements by the Tenant. At its discretion, upon written notice to the Landlord, the Tenant shall have the right to undertake such Corrective Measures and the Landlord shall reimburse the Tenant up to a total amount of $5,000,000 (or the Tenant may offset against Rent) for its reasonable and necessary documented costs therefor within thirty (30) days after receipt of an invoice by the Landlord (including any costs associated with the work stoppage or interference with the ability of any Facility Contractor to perform its respective obligations under the Facility Contracts (including mobilization and de-mobilization costs, suspension costs, storage costs, rescheduling penalties, and all other direct and indirect costs incurred by the Tenant or any Facility Contractor (and its respective subcontractors) as a result of any delay caused by such Corrective Measures)). The Party not controlling the Corrective Measures under this Section 9.4(b) shall have a reasonable right of participation in the Corrective Measures, including the right to (i) receive copies of material reports, work plans and correspondence relating to the Corrective Measures, (ii) review and comment on draft reports and work plans (and all prompt and reasonable comments shall be considered and addressed by the controlling Party in good faith), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.4(b) shall not supersede or diminish the provisions or the Landlord’s obligations under Section 9.4(a).

 

15


9.5 Survival of Indemnities. The foregoing indemnities shall survive the Initial Term, any Extended Term and any Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

10. Insurance.

10.1 Tenant Insurance. The Tenant shall carry or cause to be carried commercial general liability insurance with respect to the Site and the uses and activities of the Tenant thereon with minimum single occurrence limit of [***]. The Tenant may elect to be self-insured in amounts greater than those minimum limits, subject to Landlord approval, which approval shall not be unreasonably withheld. The Landlord will be named as an additional insured. The Tenant further covenants and agrees, at its sole expense, to take out and maintain at all times all necessary workers’ compensation insurance covering all persons employed by the Tenant in and about the Site to the extent required by Applicable Laws.

10.2 Landlord Insurance. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Site and/or any activities of the Landlord with respect to the Site in its reasonable business discretion. The Landlord may elect to be self-insured.

11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. The Landlord shall not create or permit to be created or to remain in connection with the Site, or the Facilities, the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of the Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Site or upon the Landlord’s interest in the Site or upon the Tenant’s interest in its leasehold of the Site, in accordance with Section 11.2.

11.2 Discharge of Liens.

(a) If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

 

16


(b) If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such Lien by deposit or by bonding proceedings. Any amount so paid by the non-responsible Party and all costs and expenses incurred by the non-responsible Party in connection therewith, including reasonable attorneys’ fees together with interest thereon at one percent (1%) per annum above the Wall Street Journal Prime Rate of interest published from time to time in the Wall Street Journal, from the respective dates of the non-responsible Party’s making of the payment or incurring of the cost and expense, shall constitute either additional rent payable by the Tenant under this Ground Lease or an offset against Rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Site, including without limitation, any liabilities, obligations and/or debts owed to laborers, vendors, brokers, materialmen, and other service providers, and then offset against the Rent any such amount(s) paid by the Tenant.

12. Entry on Premises by Landlord, Etc.

The Landlord and its representatives shall have no right to enter the Site, except as specifically authorized from time to time in advance in writing by the Tenant after written notice to the Tenant of such request by the Landlord; and such authorization shall be reasonably given by the Tenant, and if/when granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of the Tenant. Such entry on the Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions such that access to certain sections of the Site will be restricted.

13. Destruction by Fire or Other Casualty.

If the Facilities or any Improvements erected on the Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the willful misconduct of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Facilities or the Improvements. Without limiting Section 23.7, in the event that the Tenant so decides not to restore or reconstruct the Facilities or the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove all ruins and rubble remaining on the Site at the Tenant’s sole cost and expense.

 

17


14. Assignment; Subleasing; Right of First Refusal.

14.1 Restrictions on Landlord. The Landlord shall not assign this Ground Lease or sell the Site, in whole or in part, (including without limitation by transfer of control or otherwise) without the prior written consent of the Tenant or having complied with Section 14.3, as applicable. This Ground Lease shall inure to the benefit of and shall be binding upon the Landlord’s permitted assigns.

14.2 Restrictions on Tenant. Subject to the provisions of Section 23, the Tenant shall not assign this Ground Lease, in whole or in part, without the prior written consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least thirty (30) days prior written notice of any proposed assignment, together with a copy of the proposed assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing, including to a Leasehold Lender, (ii) to a Leasehold Lender or any purchaser upon a foreclosure of a Leasehold Mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a Leasehold Mortgage, (iii) to any Affiliate or member of the Tenant, (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder. The Tenant shall not sublease all or any portion of the Site without the prior written consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned.

14.3 Right of First Refusal. During the Initial Term or any Extended Term of this Ground Lease, the Landlord may not transfer a portion of the Site and may only transfer the entire Site through a bona fide sale in exchange for a sum certain of money. If the Landlord, during the Initial Term or any Extended Term of this Ground Lease, makes a bona fide offer to sell or receives a bona fide offer from a third party to buy or acquire (individually and collectively a “Bona Fide Offer”) all or any portion of the Site separately or as a part of a larger parcel of which the Site is a part, the Landlord will promptly, within ten (10) Business Days of such making or receipt, give written notice to the Tenant of the terms of the Bona Fide Offer made or received, including the cash price attributable to the Site. If the sale is a tract of which the Site is a part, then the cash price attributable to the Site will be that part of the cash price multiplied times a fraction, the denominator of which is the total number of acres in the Site and the numerator of which is the total number of acres in the larger tract to be sold. The notice shall also state the other terms and conditions of the proposed sale and the Landlord’s willingness to sell for that cash price and on those terms. Upon receiving the notice, the Tenant may exercise the right, in the manner specified below, to purchase either the property described in the Bona Fide Offer or the Site (or part thereof) at the lower of: (i) the stated cash price in the Bona Fide Offer or (ii) Fair Market Value, which shall not include any value of this Ground Lease, the Facilities, the Improvements and/or Landlord’s Improvements in the determination of the Fair Market Value, pursuant to the process described in Sections 14.3 through 14.6. This Section 14.3 does not apply to transfers pursuant to successions or donations executed in accordance with Louisiana law. Notice need not be given by the Landlord to the Tenant of any bona fide offer from a third party, when the Landlord does not intend to accept such offer.

 

18


14.4 Exercise of Right of First Refusal. If the Tenant elects to purchase the property or Site described in the Bona Fide Offer under the provisions of Section 14.3, or if the Tenant elects to seek the Fair Market Value under the provisions of Section 14.3, the Tenant must notify the Landlord of such election, doing so in writing delivered to the Landlord within thirty (30) Business Days after the date of the Landlord’s written notice to the Tenant of the Bona Fide Offer. If the Tenant elects to refuse the Bona Fide Offer, the Tenant need take no action whatsoever; further, if the Tenant fails to deliver to the Landlord a notice of the Tenant’s election within the time required for such notice, the Tenant will be deemed to have refused the Bona Fide Offer. If the Tenant refuses, or is deemed to have refused, the Bona Fide Offer, the Landlord is free to sell the property pursuant to the Bona Fide Offer subject to this Ground Lease, any New Lease, and any Leasehold Mortgage, any Non-Disturbance Agreement and continuation of the leasehold interest created by this Ground Lease and any New Lease.

14.5 Fair Market Valuation. If the Tenant elects to seek the Fair Market Value under the provisions of Section 14.3, then the Tenant shall notify the Landlord of the Tenant’ s proposed Fair Market Value for the property or the Site, as the case may be. Thereafter, for a period of thirty (30) days following such notice the Parties shall in good faith attempt to agree upon the Fair Market Value. If the Parties do not agree upon the Fair Market Value within such thirty (30) days, each of the Parties shall within the next thirty (30) days appoint a qualified appraiser to appraise the Fair Market Value (the “First Appraiser” and the “Second Appraiser”) by notice to the other Party. If the Second Appraiser is not timely designated, the determination of the Fair Market Value shall be made solely by the First Appraiser. The First Appraiser, or each of the First Appraiser and the Second Appraiser if the Second Appraiser is timely designated, shall submit its determination of the Fair Market Value to the Parties within thirty (30) days of the date of its selection (or the selection of the Second Appraiser, as applicable). If there are two (2) appraisers and their respective determinations of the Fair Market Value vary by less than ten percent (10%) of the higher determination, the Fair Market Value shall be the average of the two determinations. ‘If such determinations vary by ten percent (10%) or more of the higher determination, the two appraisers shall promptly designate a third appraiser (the “Third Appraiser”). Neither the Tenant nor the Landlord shall provide, and the First Appraiser and Second Appraiser shall be instructed not to provide, any information to the Third Appraiser as to the determinations of the First Appraiser and the Second Appraiser or otherwise influence such Third Appraiser’s determination in any way. The Third Appraiser shall submit its determination of the Fair Market Value to the Parties within thirty (30) days of the date of its selection. The Fair Market Value shall be equal to the average of the two closest of the three determinations. The determination of the Fair Market in accordance with the foregoing procedure shall be final and binding on the Parties. If any appraiser is only able to provide a range in which Fair Market Value would exist, the average of the highest and lowest value in such range shall be deemed to be such appraiser’ s determination of the Fair Market Value. Each appraiser selected pursuant to the provisions of this Section 14.5. shall be a qualified Person with prior experience in appraising industrial lands in south Louisiana and that is not an interested Person with respect to either Party or such Party’s Affiliates. If the Tenant has invoked this process and when the Fair Market Value has been determined, then the Tenant must notify the Landlord in writing within thirty (30) days that the Tenant elects to purchase the property or Site at the lower of either the Fair Market Value determined or the Bona Fide Offer; and if the Tenant fails to notify the Landlord within this thirty (30) day period, then the Landlord is free to sell the property or Site pursuant to the Bona Fide Offer subject to this Ground Lease and any Leasehold Mortgage, any New Lease and any Non-Disturbance Agreement, and continuation of the leasehold interest created by this Ground Lease.

 

19


14.6 Continuation of Right. If for any reason the Site is not sold by the Landlord following a Bona Fide Offer from a third-party, the right of first refusal granted and described in the preceding Sections 14.1 through 14.5 shall continue in full force and effect, on the same terms and conditions.

15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of ten (10) days after written notice thereof from the Landlord to the Tenant.

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15.1(a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Site or discharge from the Site shall not constitute an Event of Default.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages; Termination. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default, the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the Tenant shall be liable for such reasonable damages unless such Event of Default is reasonably remedied in a timely manner and all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default, together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and payable, and all costs and expenses reasonably incurred by or on behalf of the Landlord as a result of the Event of Default, including reasonable attorneys’ fees, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective and is not valid if the Landlord does not give prior written notice to the Tenant pursuant to Section 15.1 (b).

 

20


(b) Landlord’s Right to Cure Tenant’s Event of Default. Upon the occurrence of an Event of Default of the Tenant which is not cured or having commenced curing by the Tenant within sixty (60) days as provided in Section 15.2(a), then, subject to the prior written consent of any Leasehold Lender under Section 23, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others to cure the Event of Default. The Tenant shall be responsible for all costs, including attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord.

(c) Sole Recourse. The sole recourse of the Landlord for any damages or liabilities due hereunder shall be limited to the assets of the Tenant, without recourse individually or collectively to the assets of the members or the affiliates of the Tenant, its lenders, or their respective directors, agents, members, shareholders, managers, employees, representatives, partners, and officers.

15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Site to the Landlord, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Site and may have, hold, and enjoy the Site; and (ii) all obligations of the Tenant hereunder for additional rent or any portion thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. In the event of any termination, the Landlord shall be under a duty to seek a successor tenant. If the Landlord obtains a successor tenant during what would have been the remainder of the term of this Ground Lease, the Tenant shall receive a credit for rentals collected from said successor tenant for the remaining term of this Ground Lease. If no successor tenant is obtained, the Tenant shall be liable for Rent obligations otherwise provided for in this Ground Lease.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

16. Events of Default of the Landlord.

16.1 Landlord’s Event of Default; Right to Cure. Any failure of the Landlord to perform and/or to comply with any of its obligations, covenants, agreements, terms, or conditions contained in this Ground Lease shall constitute a “Landlord’s Event of Default” hereunder. The Landlord shall have sixty (60) days after written notice by the Tenant to the Landlord of Landlord’s Event of Default to fully cure Landlord’s Event of Default.

 

21


16.2 Tenant’s Remedies; Cure. In the event of a Landlord’s Event of Default that is not fully cured under Section 16.1, in addition to all other remedies available to the Tenant, the Tenant may cancel this Ground Lease by written notice to the Landlord. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof, and shall be immediately payable to the Tenant. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default that is not fully cured under Section 16.1.

16.3 Tenant’s Right to Cure Landlord’s Event of Default. Upon the occurrence of a Landlord’s Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord’s Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others, purchasing the required goods or services and procuring necessary insurance. The Landlord shall be responsible for all costs including attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

17. Mutual Obligations.

17.1 Late Charges; Interest. If any Rent or other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of fifteen (15) days after receipt of written notice, such sum shall bear a late charge equal to one percent (1.0%) of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

 

22


17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise (excluding, however, specific performance against the Tenant) and the exercise or beginning of the exercise by the Parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by email or United States registered or certified mail, return receipt and signature requested, postage prepaid, to the Parties at the following addresses:

 

To the Tenant:

   Venture Global CP2 LNG, LLC
   1001 19th St North
   Suite 1500
   Arlington, VA 22209
   Attention: [***]
   Email: [***]

With a copy to:

   Venture Global CP2 LNG, LLC
   1001 19th St North
   Suite 1500
   Arlington, VA 22209
   Attention: [***]
   Email: [***]

To the Landlord:

   Wilma Davis Bride Family, LLC
   2887 Coffey Farms Road,
   Lake Charles, LA 70611
   Attention: [***]
   Email: [***]

or to such other numbers or addresses as either above designated recipients may from time to time designate by written notice to the other designated recipient hereto at least fifteen (15) days in advance of an effective date stated therein.

18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mail, return receipt and signature requested, postage prepaid.

 

23


19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable possession of the Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Site during the Initial Term, any Extended Term and any Removal Period of this Ground Lease without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord. This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow compatible use of the remainder of their property adjacent to the Site and will not create or allow the creation of a visual, olfactory or auditory nuisance on said remainder of their property.

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that: (i) it is the sole owner of good title to all of the Site; (ii) the Site is subject to no Liens, privileges, encumbrances, defects in title, servitudes, easements, restrictions, dedications, leases, mineral leases, reservations or other exceptions to title; (iii) during the term hereof it shall not encumber the Site; (iv) it is authorized to make this Ground Lease for the term hereof; (v) the provisions of this Ground Lease do not and will not conflict with or violate any of the provisions of existing agreements between the Landlord and any third party; and (vi) the Landlord will deliver the Site free of all tenants and occupants and claims thereto. Tenant recognizes that Landlord does not have an abstract of title, and does not require Landlord to produce one.

20. Eminent Domain.

20.1 Complete Condemnation. If, during the term hereof, the whole of the Site shall be taken under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking) by any public or private authority, then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided that the Tenant shall share in the condemnation award as provided herein. The Tenant may continue to occupy the Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Site from and after the date of such taking.

20.2 Partial Condemnation. If, during the term hereof, any public or private authority shall, under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking), makes a taking resulting in the reduction of the surface area of the Site by fifteen percent (15%) or more, or of fifteen percent (15%) or more of the value of the Facilities, the Improvements or the Landlord’s Improvements, or resulting in material interference to the Tenant’s ability to use in a commercially reasonable manner the remainder of the Site, the Facilities, the Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of the exercise of

 

24


its election within one-hundred twenty (120) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2, the term hereof shall cease and terminate as of the last day of the calendar month in which such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant, and the Tenant shall share in the condemnation award as provided herein.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the term hereof shall continue in full force and effect, and the monthly Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete taking pursuant to Section 20.1, the Tenant will be entitled to receive the portion of the condemnation award (or settlement) attributable to (i) the value of the Facilities, the Improvements, and Landlord’s Improvements, and fixtures and other property located on the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, plus (iii) other compensation or benefits paid as a consequence of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking (if any such compensation or benefits are paid by the applicable taking authority) and the Landlord shall be entitled to recover that portion of the condemnation award (or settlement) fairly attributable to the value of the land taken. In the event Tenant’s Property, the Improvements, or the Facilities are not taken, the Tenant shall not be entitled to any portion of the award, and in the event no Landlord’s property is taken, the Landlord shall not be entitled to any portion of the award. In the event of a partial taking of the Improvements, the Tenant’s Property and/or Facilities, the entire award or settlement shall be paid to the Tenant. In the event of a partial taking of the Site, the Tenant will be entitled to receive the portion of the award attributable to (i) the value of the portion of the Facilities, Improvements and Tenant’s Property located in the portion of the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, plus (iii) damage to the remaining Facilities, and the Tenant will promptly restore the remaining portion of the Facilities to the extent of the award payable to the Tenant. Nothing contained herein shall prohibit the Tenant’s claiming relocation damages or damages for lost profits or loss of leasehold advantage against the taking authority in any appropriate proceeding.

21. Temporary Taking or Other Deprivation.

If, during the term hereof, (i) less than all of the Landlord’s title to all or any portion of the Site is taken for temporary use or occupancy, or (ii) any public or private authority takes any action not resulting in a taking of all or any portion of the Site but resulting in a right to compensation therefor, such as changing of the grade of any street upon which the Site abuts, then, except as otherwise provided in Section 20, the Tenant shall be entitled to make claim for, recover, and retain all awards, whether pursuant to judgment, agreement, or otherwise, recoverable in connection therewith.

 

25


22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure, provided that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section shall govern and control.

23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant. The term “Leasehold Mortgage” shall mean, at any point in time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Site and this Ground Lease. It is acknowledged and agreed that, during the term of this Ground Lease, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the term of this Ground Lease, the Tenant shall provide the Landlord with written notice of the identity, contact information and address for each Leasehold Lender (or the agent authorized to act on behalf of the Leasehold Lender), such notice to be provided to the Landlord by the Tenant within no less than a calendar year within which the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

23.2 Right to Perform for Tenant: Right to Cure.

(a) In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and the Landlord shall accept such performance by Leasehold Lender with the same force and effect as if furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing.

 

26


(b) If any default in the performance of an obligation of the Tenant under this Ground Lease is not susceptible to being cured by Leasehold Lender, the Landlord shall have no right to terminate this Ground Lease with respect to such default and such default shall be deemed waived for the benefit of Leasehold Lender only, provided that:

(i) Leasehold Lender shall have commenced to cure (i) any other non-payment default of the Tenant that is susceptible to being cured by Leasehold Lender and (ii) any default in the payment of any portion of Rent, in each case, within the time periods prescribed under Section 23.2(a);

(ii) Leasehold Lender (or its designee) shall have commenced to acquire the Tenant’s interest in this Ground Lease and the Site or to commence foreclosure or other appropriate proceedings under the Leasehold Mortgage within the time periods prescribed under Section 23.2(a);

(iii) if Leasehold Lender (or its designee) shall acquire the Tenant’s interest in this Ground Lease and/or the Site, Leasehold Lender (or its designee) shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition; and

(iv) if any third party shall, by foreclosure or dation en paiement under the Leasehold Mortgage or by assignment or other transfer from Leasehold Lender, acquire the Tenant’ s interest in and to the Site under this Ground Lease, such third party shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by a third party with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition.

However, if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then notwithstanding any provision in this Section 23 to the contrary, the Landlord may exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

 

27


23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’ s prior written consent, and any such action taken without Leasehold Lender’ s consent shall not be binding on the Tenant or Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.4 Delivery of Notices. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including, without limitation, any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been delivered to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in writing to the Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’s interests in the Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including, without limitation, the acquisition of the Tenant’s interest in this Ground Lease and the Site created thereby in a transaction described in this Section 23 or the taking of possession of the Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender, provided that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Site.

 

28


23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23 .2, the purchaser at any sale of this Ground Lease and the interests in and to the Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including, without limitation, power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Site thereby created under any instrument of assignment or transfer in lieu of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Site thereby created.

23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, substantially all, or any part of the Site or the Tenant’s Facilities. Rent shall continue to be due and payable as set forth in this Ground Lease.

23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent domain proceeding of all, substantially all, or any part of the Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Facilities, the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Site created by this Ground Lease and the value of the leasehold improvements located on the Site, up to an amount equaling the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Facilities and/or the Tenant’s interest in, under and to this Ground Lease; provided that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under applicable law to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this Ground Lease. In the event of a taking of a portion of the Site, the Rent shall be reduced pro rata based upon the portion of the Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease.

 

29


23.9 New Direct Lease.

(a) If this Ground Lease is canceled or terminated for any reason (except in connection with a Bankruptcy Proceeding, for which the provisions of Section 23.10 are hereby agreed upon by the Landlord and the Tenant), and provided that Leasehold Lender has (i) commenced to cure and continues diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, and (ii) cured any payment default in respect of any portion of Rent, the Landlord hereby agrees that the Landlord shall, upon Leasehold Lender’s written election within one hundred twenty (120) days of such cancellation or termination, promptly enter in a new, direct lease with Leasehold Lender (or its nominee or any other party which Leasehold Lender may designate, including without limitation, the Tenant) with respect to the Site on the same terms and conditions as this Ground Lease (a “New Lease”), it being the intention of the parties to preserve this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Said New Lease shall be superior to all rights, liens and interests intervening between the date of this Ground Lease and the granting of the New Lease and shall be free of any and all rights of the Tenant under this Ground Lease.

(b) The Tenant and the Landlord acknowledge and agree that Leasehold Lender shall have the right to encumber such direct New Lease and the estate created thereby with a deed of trust or a mortgage (as the case may be) on the same terms and with the same lien priority as the Leasehold Mortgage, it being the intention of the parties to preserve the priority of the Leasehold Mortgage, this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. If this Ground Lease is rejected, cancelled or terminated for any reason and Leasehold Lender, its nominee or a designee of Leasehold Lender enters into a direct lease with the Landlord with respect to the Site, the Landlord hereby agrees that it will execute such documents as Leasehold Lender may require in order to ensure that the new direct lease provides for customary leasehold mortgagee protections, including without limitation, protections similar to those contained herein.

23.10 Bankruptcy. In the event of a proceeding under the United States Bankruptcy Code (Title 11 U.S.C.) as now or hereafter in effect (a “Bankruptcy Proceeding”):

(a) If this Ground Lease is rejected in connection with a Bankruptcy Proceeding by the Tenant or a trustee in bankruptcy (or other party to such proceeding) for the Tenant, such rejection shall be deemed an assignment by the Tenant to the Leasehold Lender of the Tenant’s Property and all of the Tenant’s interest under this Ground Lease, and this Ground Lease shall not terminate and the Leasehold Lender shall have all rights and obligations of the Tenant as if such Bankruptcy Proceeding had not occurred, unless Leasehold Lender shall reject such deemed assignment by notice in writing to the Landlord within thirty (30) days following rejection of this Ground Lease by the Tenant or the Tenant’s trustee in bankruptcy. If any court of competent jurisdiction shall determine that this Ground Lease shall have been terminated notwithstanding the terms of the preceding sentence as a result of rejection by the Tenant or the trustee in connection with any such proceeding, the rights of Leasehold Lender to a New Lease from the Landlord pursuant to Section 23.9 hereof shall not be affected thereby.

 

30


(b) In the event of a Bankruptcy Proceeding against the Landlord:

(i) If the bankruptcy trustee, the Landlord (as debtor-in-possession) or any party to such Bankruptcy Proceeding seeks to reject this Ground Lease pursuant to United States Bankruptcy Code §365(h)(1), the Tenant shall not have the right to treat this Ground Lease as terminated except with the prior written consent of Leasehold Lender and the right to treat this Ground Lease as terminated in such event shall be deemed assigned to Leasehold Lender, whether or not specifically set forth in the Leasehold Mortgage, so that the concurrence in writing of the Tenant and the Leasehold Lender shall be required as a condition to treating this Ground Lease as terminated in connection with such Bankruptcy Proceeding.

(ii) Unless this Ground Lease is treated as terminated in accordance with Section 23.10(b)(i), then this Ground Lease shall continue in effect upon all the terms and conditions set forth herein, including Rent, but excluding requirements that are not then applicable or pertinent to the remainder of the term of this Ground Lease. Thereafter, the Tenant or its successors and assigns shall be entitled to any offsets against Rent payable hereunder for any damages arising from such bankruptcy, to the extent the Tenant’s operation of business has been materially interfered with, and any such offset properly made shall not be deemed a default under this Ground Lease. The lien of the Leasehold Mortgage shall extend to the continuing possessory rights of the Tenant following such rejection with the same priority as it would have enjoyed had such rejection not taken place.

23.11 Estoppel Certificates; Non-Disturbance Agreements.

(a) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel’’) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under this Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant thereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that each of this Ground Lease and the Non-Disturbance Agreement, true, correct copies of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, have not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Landlord’s power and authority

 

31


to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, and any Non-Disturbance Agreement, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or mitten, to which Landlord is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the Landlord Estoppel, the present lessor under this Ground Lease and owns good and indefeasible title to the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (xix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

(b) Within fifteen (15) days following Leasehold Lender’s or the Landlord’s written request, the Tenant shall provide Leasehold Lender with an estoppel certificate (the “Tenant Estoppel”) which shall certify to such requesting Leasehold Lender (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or noncompliance by the Landlord of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Landlord of any other conditions required under this Ground Lease, (iii) as to any existing default of the Landlord under this Ground Lease, or alternatively that the Landlord is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Landlord hereunder, and as to any existing event or condition in existence as of the date of the Tenant Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Tenant to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Tenant, (v) that this Ground Lease, a true and correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the

 

32


agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Tenant’s power and authority to execute the Tenant Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Tenant asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Tenant from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties, or other sums, whether or not constituting rent, due and owing as of the date of the Tenant Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which the Tenant is a party (other than those set forth on a schedule to the Tenant Estoppel), (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Tenant Estoppel, (xiv) that the Tenant is, as of the date of the Tenant Estoppel, the present lessee under this Ground Lease and holds a valid leasehold interest in the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Tenant has not assigned, sublet, hypothecated, leased, or otherwise transferred it interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Tenant’s interest in the Site, other than those set forth on a schedule to the Tenant Estoppel, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Tenant is a party or by which the Tenant is otherwise bound affecting the Tenant’s interest in and to the Site, (xvii) that the Tenant has not commenced any action or sent any notice to the Landlord for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Tenant is not, as of the date of the Tenant Estoppel, entitled to terminate, cancel, modify, or surrender this Ground Lease, and (xviii) as to such other matters related to this Ground Lease as such Leasehold Lender may reasonably determine from time to time.

(c) Within fifteen (15) days following Leasehold Lender’ s or the Tenant’ s written request, the Landlord shall enter into a non-disturbance agreement with Leasehold Lender or its designee, in the form attached hereto as Exhibit 5 (a “Non-Disturbance Agreement”).

23.12 No Termination by Confusion. There shall be no termination by confusion of this Ground Lease or any interest in this Ground Lease or of the interests in and to the Site created thereby with the fee estate in the Site, by reason of the fact that this Ground Lease or such interest therein, may be directly or indirectly held by or for the account of any person who shall hold any interest in the fee estate in the Site, nor shall there be a merger by reason of the fact that all or any part of the interests in and to the Site created by this Ground Lease may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any interest in the fee estate in the Site or any interest of the Landlord under this Ground Lease.

 

33


23.13 Landlord’s Recognition of Tenant. The Landlord hereby recognizes the Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that the Tenant acquired its interest in this Ground Lease and in and to the Site in accordance with the terms of this Ground Lease.

23.14 Agreement to Amend. The Landlord recognizes the importance of the Tenant’s ability to obtain Leasehold Mortgages, and that the provisions of this Ground Lease may be subject to the approval of a Leasehold Lender. If any Leasehold Lender should require, as a condition to such financing, any reasonable modifications of this Ground Lease, whether for purposes of clarifying the provisions of this Ground Lease or to include provisions then customary for leasehold financing transactions, the Landlord agrees to execute the appropriate amendments to this Ground Lease; provided, however, that no such modification shall, to the detriment of the Landlord, impair any of the Landlord’s rights, as reasonably determined by the Landlord or increase any of the Landlord’s obligations, as reasonably determined by the Landlord, under this Ground Lease.

23.15 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

23.16 Subordination of Landlord’s Lien. The Landlord hereby subordinates any lien or privilege it may have on any movables found from time to time in or upon the Site, including without limitation, the Landlord’s privileges pursuant to La. Civil Code articles 2707, et seq., to any Leasehold Lender’s rights under this Section 23 and the lien of any Leasehold Mortgage.

24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

24.2 Successors. The covenants, agreements, terms, provisions, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties hereto.

24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

 

34


24.6 No Oral Change or Termination. This Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties hereto with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

24.9 Litigation. In case of any litigation between the Parties hereto regarding the subject matter hereof, the losing Party shall pay all reasonable costs and expenses (including reasonable attorneys’ fees) of the prevailing Party. The venue of any litigation shall be a state court of competent jurisdiction the Thirty-Eighth Judicial District Court, Parish of Cameron, State of Louisiana, unless the default or dispute implicates or involves a federal statute, regulation, order, or permit, in which case venue shall be in the federal courts for the Western District of Louisiana.

24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

24.11 Authority. Each of the Landlord and the Tenant represents and warrants that it has the authority to enter into this Ground Lease, that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date, (a) the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 3, evidencing its authority to execute and perform under this Ground Lease and (b) the Landlord shall deliver to the Tenant a resolution in the form attached hereto as Exhibit 4, evidencing its authority to execute and perform under this Ground Lease.

24.12 Brokers and/or Real Estate Agents. Each of the Landlord and the Tenant represents, acknowledges and agrees that it is not represented by any real estate broker/agent and that it is not responsible for payment of any commissions to any real estate brokers/agents in connection with this Ground Lease.

 

35


24.13 Legal Relationships; Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. There is no third party beneficiary of this Ground Lease, except as provided in Section 23.15 and any rights of a Leasehold Lender as provided herein. This Ground Lease is the product of the Parties joint negotiation and equal drafting thereof. The language of this Ground Lease shall be construed as a whole according to its fair meaning and not construed strictly for or against any of the Parties pursuant to any statue, case law or rule of interpretation or construction to the contrary.

24.14 Further Assurances. In connection with this Agreement and the transactions contemplated hereby, each Party shall execute and deliver any · additional documents and instruments and perform any additional acts that may be necessary or appropriate to effectuate and perform the provisions of this Agreement and those transactions, including in connection with the requests of any Financing Parties or Leasehold Lender.

24.15 No Waiver or Surrender. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Site and no agreement to accept a surrender of the Site shall be valid unless it is in writing and signed by the Landlord.

24.16 Memorandum of Lease. The Parties hereto agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’ s interest hereunder; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease.

[Remainder of page left intentionally blank; signatures on following pages]

 

36


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

    LANDLORD:

/s/ Jonathan M. Robillard

    WILMA DAVIS BRIDE FAMILY, LLC
WITNESS Jonathan M. Robillard      
    By:  

/s/ Kathy L. Guthrie

/s/ Brandi V. Bell

    Name: Kathy L. Guthrie
WITNESS Brandi V. Bell     Title: Member / Manager

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Calcasieu and State of Louisiana, personally came and appeared Kathy L. Guthrie, who, after being sworn by me, did execute this agreement on the 12th day of October, 2023 at Lake Charles, State of Louisiana.

 

/s/ M. Keith Prudhomme

NOTARY PUBLIC

 

   

TENANT:

 

/s/ Tracy Pelt

    VENTURE GLOBAL CP2 LNG, LLC
WITNESS Tracy Pelt    

 

By:

 

 

/s/ Keith Larson

 

/s/ Jeff Layman

   

Name: Keith Larson

Title: Secretary

WITNESS Jeff Layman    

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 6th day of October, 2023 at Arlington, State of Virginia.

 

/s/ Michael Eliezer Millan

NOTARY PUBLIC

 

1


LIST OF EXHIBITS

 

Exhibit 1    Legal Description of the Site
Exhibit 2    Site Survey
Exhibit 3    Tenant’s Resolution
Exhibit 4    Landlord’s Resolution
Exhibit 5    Form of Non-Disturbance Agreement

 

39


EXHIBIT 1

LEGAL DESCRIPTION OF THE SITE

PARCEL “O”

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE HALF INCH DIAMETER IRON PIPE; THENCE S.89°23’14”E., A DISTANCE OF 4,151.02 FEET TO THE NORTHWEST CORNER OF SECTION 8, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE AND BEING THE POINT OF BEGINNING; THENCE S.89°02’59”E., A DISTANCE OF 915.42 FEET ALONG THE NORTH LINE OF SAID SECTION 8 TO THE NORTHWEST CORNER OF SECTION 9, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE HALF INCH DIAMETER IRON PIPE; THENCE S.89°02’59”E., A DISTANCE OF 928.62 FEET ALONG THE NORTH LINE OF SAID SECTION 9 TO THE NORTHEAST CORNER OF SECTION 9, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE HALF INCH DIAMETER IRON PIPE AND A FOUND TWO INCH DIAMETER IRON PIPE, OFFSET 0.47’ N.16°27’54”E. OF TRUE POSITION; THENCE S.00°56’35”W., A DISTANCE OF 1,351.20 FEET ALONG THE EAST LINE OF SAID SECTION 9 TO A POINT BEING MARKED BY A FOUND QUARTER INCH DIAMETER IRON BAR; THENCE S.00°56’35”W., A DISTANCE OF 2,979.00 FEET ALONG THE EAST LINE OF SAID SECTION 9 TO A POINT BEING MARKED BY A FOUND ONE INCH DIAMETER IRON PIPE; THENCE N.89°02’21”W., A DISTANCE OF 437.08 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE N. 89°02’21”W., A DISTANCE OF 491.73 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE N.89°02’2l”W., A DISTANCE OF 471.18 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE N.89°02’21”W., A DISTANCE OF 455.02 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON PIPE; THENCE N.01°l1’40”E., A DISTANCE OF 624.69 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°58’57”E., A DISTANCE OF 930.52 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°59’32”E., A DISTANCE OF 785.80 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.01°19’50”E., A DISTANCE OF 814.24 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.01°19’17”E., A DISTANCE OF 84.97 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°56’33”E., A DISTANCE OF 759.51 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°56’33”E., A DISTANCE OF 330.15 FEET TO THE POINT OF BEGINNING. SAID DESCRIBED PARCEL, CONTAINING 8,008,279.09 SQUARE FEET OR 183.8448 ACRES, IS SITUATED IN SECTIONS 8 AND 9 TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA.

 

40


EXHIBIT 2

SITE SURVEY

[Omitted]


EXHIBIT 3

TENANT’S RESOLUTION

[Omitted]


EXHIBIT 4

LANDLORD’S RESOLUTION

[Omitted]


EXHIBIT 5

FORM OF NON-DISTURBANCE AGREEMENT

[Omitted]

Exhibit 10.58

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

STATE OF LOUISIANA

PARISH OF CAMERON

GROUND LEASE AGREEMENT

(136 Acres)

This GROUND LEASE AGREEMENT (this “Ground Lease”) is executed and effective as of October 12, 2023 (the “Ground Lease Commencement Date”), by and between Venture Global CP2 LNG, LLC,, a Delaware limited liability company (the “Tenant”), and Ardoin Henry, LLC, a Louisiana limited liability company (the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Cameron Parish, Louisiana, which comprises approximately one hundred thirty-six (136) acres; and

WHEREAS, the Tenant wishes to lease land owned by the Landlord for the construction, development and operation of a natural gas liquefaction facility and liquefied natural gas (“LNG”) export terminal (the “Facilities”) and other uses permitted by this Ground Lease; and

WHEREAS, in accordance with the above, the Tenant has executed this Ground Lease and offers fair value to the Landlord as cause and consideration for this Ground Lease.

NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this Ground Lease, and the Parties herein covenant and agree as follows:

1. Definitions and Interpretation.

As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

“Adjustment Period” has the meaning set forth in Section 4.l(c).

“Affiliate” means any Person controlled by, controlling or under common control with the Landlord or the Tenant, as applicable. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of thirty percent (30%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.

“Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Site.


“Bankruptcy Proceeding” has the meaning set forth in Section 23.10.

“Bona Fide Offer” has the meaning set forth in Section 14.3.

“Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in the State of New York are authorized or required by law to close.

“Consumer Price Index” has the meaning set forth in Section 4.2.

“Corps” has the meaning set forth in Section 8.3(a).

“CPI Adjustment” has the meaning set forth in Section 4.1.

“CPI Disagreement Notice” has the meaning set forth in Section 4.2.

“CPI Notice” has the meaning set forth in Section 4.2.

“CPI Percentage Increase” has the meaning set forth in Section 4.2.

“Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Law relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

“Event of Default” has the meaning set forth in Section 15.1.

“Extended Term” has the meaning set forth in Section 3.2.

“Facilities” has the meaning set forth in the Recitals hereof.

“Facility Contractors” means, collectively, the Persons engaged by the Tenant to construct the Facilities and/or develop the Facilities, the Site and/or the Improvements.

“Facility Contracts” means, collectively, the contracts entered into by the Tenant in connection with the design, construction, equipment procurement, operation and maintenance of the Facilities, the Site and/or the Improvements.

“Fair Market Value” means the value determined pursuant to the process set forth in Section 14.5.

 

2


“Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Facilities, the Improvements, the Site, or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders.

“First Appraiser” has the meaning set forth in Section 14.5.

“Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, droughts, floods, washouts, explosions, breakage or accident or necessity of repairs to machinery or equipment or lines of pipe; (ii) weather related events affecting an entire geographic region; (iii) acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, terrorism, discovery of burial grounds or human remains or legally protected artifacts, insurrections or wars; (iv) the failure or interruption of performance by the Tenant’s engineering, procurement and construction contractor or any subcontractors of such contractor to the extent caused by an event of Force Majeure under this Ground Lease; (v) the failure or interruption of performance by the Tenant’s suppliers by reason of such supplier’s valid declaration of an event that would constitute an event of force majeure under the Tenant’s contract with such supplier; and (vi) governmental actions such as necessity for compliance with any court order, law, statute, ordinance, regulation, or policy having the effect of law promulgated by a Governmental Authority having jurisdiction, or that restrict the Tenant’s ability to reasonably construct and/or operate the Facilities or the Improvements or any delay in issuance or effectiveness of any Governmental Approval that has been properly applied for by the Tenant that is required to construct and/or operate the Facilities or the Improvements.

“Governmental Approval” means any authorization, waiver, consent, approval, license, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority.

“Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

“Ground Lease” has the meaning set forth in the Preamble hereof.

“Ground Lease Commencement Date” has the meaning set forth in the Preamble hereof.

 

 

3


“Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

“Hazardous Substances Law” means any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent it relates to the handling of and exposure to hazardous or toxic materials or similar substances.

“Improvements” means any and all improvements made by Tenant, in its sole discretion, to the Site, including but not limited to, improvements relating to the loading, unloading, handling, treatment, processing, producing, transporting, distributing, selling, metering and/or storing of (i) natural gas, natural gas liquids, and other natural gas products, derivatives and by-products and (ii) other petroleum and hydrocarbon liquids, gases, products, derivatives and by-products, including but not limited to (A) the importation, regasification, production, exportation, liquefaction, refinement, enhancement, other treatment and transportation (including by ship, pipeline, truck or rail) of LNG, and LNG by-products and additives and (B) the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of any improvements, component parts and other constructions, fixtures, facilities, equipment and/or appurtenances (including natural gas pipelines, natural gas liquids extraction, processing and delivery facilities, acid gas removal units, natural gas liquefaction trains, LNG regasification facilities, and other treatment facilities, cryogenic pipelines, LNG storage tanks, petroleum and other hydrocarbon liquids storage facilities, nitrogen storage and processing facilities, power generation and transmission infrastructure, marine, rail and trucking receipt, delivery and servicing facilities (including piers, marine terminals, bulkheads, wharfs, docks, inlets, wetslips, moonpools, moorings, jetties, and loading and unloading equipment), and other utilities and facilities (including berms, open space, security fencing, control rooms, offices, warehouses, parking and yards), in each case, necessary, ancillary or desirable to the Tenant in connection with the foregoing.

 

4


“Initial Term” has the meaning set forth in Section 3.1.

“Landlord” has the meaning set forth in the Preamble hereof.

“Landlord Estoppel’’ has the meaning set forth in Section 23.1l(a).

“Landlord Indemnitee” has the meaning set forth in Section 9.1.

“Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, affiliates, invitees, agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Site and/or Landlord’s Improvements.

“Landlord’s Event of Default” has the meaning set forth in Section 16.1.

“Landlord’s Improvements” has the meaning set forth in Section 6.1.

‘‘Lease Year” means a period of twelve (12) consecutive full calendar months. The first Lease Year shall begin on the Ground Lease Commencement Date. Each succeeding Lease Year shall commence upon the anniversary of the first day of the previous Lease Year.

“Leasehold Lenders” has the meaning set forth in Section 23.1.

“Leasehold Loan” has the meaning set forth in Section 23.1.

“Leasehold Mortgage” has the meaning set forth in Section 23.1.

“Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

“LNG” has the meaning set forth in the Recitals hereof.

“Minerals” has the meaning set forth in Section 8.3(b).

“New Lease” has the meaning set forth in Section 23.9(a).

‘‘Non-Disturbance Agreement” has the meaning set forth in Section 23.1l(c).

“Option Agreement” means the Real Estate Lease Option Agreement between Landlord and Tenant (as successor in interest to Cameron Land Ventures, LLC), dated as of August 24, 2020.

 

5


“Party” or “Parties” has the meaning set forth in the Preamble hereof.

“Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

“Property Taxes” means all real (immovable) and personal (movable) property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

“Removal Period” means the period of time that is required by Tenant to remove any and all of Tenant’s Property, including the Facilities and/or Improvements, from the Site in accordance with Section 7.1.

“Rent” has the meaning set forth in Section 4.1.

“Second Appraiser” has the meaning set forth in Section 14.5.

“Site” means the real (immovable) property of approximately one hundred thirty-six (136) acres described in the legal description set forth in Exhibit 1, and illustrated by the Survey Map attached as Exhibit 2, upon which the Facilities and any Improvements will be located and which real (immovable) property is owned by the Landlord.

“Surface Waiver” has the meaning set forth in Section 8.3(b).

“Survey Map” means the ALTA survey of the Site, dated April 9, 2020, by Lonnie G. Harper & Associates, Inc., attached as Exhibit 2.

“Tenant” has the meaning set forth in the Preamble hereof.

“Tenant Estoppel” has the meaning set forth in Section 23.1l(b).

“Tenant Indemnitee” has the meaning set forth in Section 9.3.

“Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Site by or on behalf of the Tenant, including the Facilities and any Improvements.

“Third Appraiser” has the meaning set forth in Section 14.5.

 

6


1.2 Interpretation. Unless the context otherwise requires:

(a) Words singular and plural in number will be deemed to include the other and pronouns having a masculine or feminine gender will be deemed to include the other;

(b) Any reference to this Ground Lease or any other contract or agreement in respect of the Site means such agreement and all schedules, exhibits and attachments thereto as may be amended, supplemented or otherwise modified and in effect from time to time, and shall include a reference to any document which amends, modifies or supplements it, or is entered into, made or given pursuant to or in accordance with its terms;

(c) The terms “hereof/’ “herein,” “hereby,” “hereto” and similar words refer to this entire Agreement and not any particular Section, subsection or other subdivision of, or Exhibit, appendix or schedule to, this Ground Lease;

(d) The terms “include” and “including” shall be construed as being at all times followed by the words “without limitation” or “but not limited to” unless the context specifically indicates otherwise;

(e) References to “Article,” “Section” or “Exhibit” are to this Ground Lease unless specified otherwise;

(f) References to any law, statute, rule, regulation, notification or statutory provision (including Applicable Laws) shall be construed as a reference to the same as it may have been, or may from time to time be, amended, modified or re-enacted;

(g) References to any Person shall be construed as a reference to such Person’s successors, heirs and permitted assigns; and

(h) The word “or” will have the inclusive meaning represented by the phrase “and/or”.

2. Ground Lease Premises.

2.1 Date. The date of this Ground Lease is the Ground Lease Commencement Date.

2.2 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of the rents and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does lease to the Tenant and the Tenant hereby leases from the Landlord, the Site and Landlord’s Improvements.

2.3 Servitudes. In addition, the Landlord shall without cost to the Tenant, grant from time to time to the Tenant and others designated by the Tenant any easements, servitudes, and rights of way for access and electricity, communications, gas, water, sewer and other utility lines, products and materials from and to the Site over land and waterways sufficient to permit the Tenant to access adjacent lands owned by the Landlord and to accomplish its purposes in connection with the Improvements or the Facilities.

 

7


2.4 Mineral Rights. Landlord’s mineral rights are specifically reserved, subject to the provisions regarding use, as set forth in Section 8.2 of this Ground Lease.

3. Term

3.1 Initial Term. The initial term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on the thirtieth (30th) anniversary of the last day of the month immediately preceding the Ground Lease Commencement Date (the “Initial Term”).

3.2 Extensions.

(a) In consideration of and conditioned upon there being no uncured Event of Default on the part of the Tenant at the time an option is exercised, the Landlord hereby grants unto the Tenant the option to lease the Site for four (4) additional ten (10) year terms. If the extension option is exercised in accordance with Section 3.2(b), the first of said additional terms shall commence upon the expiration of the Initial Term and extend for a period of ten (10) years and each of said additional terms shall commence upon the expiration of the then-current additional term and extend for a period of ten (10) years. Each of such additional terms is referred to herein as an “Extended Term” and, collectively, the Initial Term and any Extended Terms are referred to herein as the “Term”.

(b) The option to extend this Ground Lease of the Site as set forth in Section 3.2(a) must be exercised in each case, if at all, by written notice from the Tenant to the Landlord on or before the date that is three (3) months prior to the expiration of the Initial Term or the then-current Extended Term, as applicable. The failure of the Tenant to timely exercise the first Extended Term or any subsequent Extended Term shall automatically terminate the right of the Tenant to exercise its option to lease the Site in any subsequent Extended Term.

(c) All the terms and conditions of this Ground Lease shall be applicable to any Extended Term and the Rent payable by the Tenant for any Extended Term shall be in accordance with the provisions set forth in Article 4.

4.1 Rent. Commencing upon the Ground Lease Commencement Date, the initial rent for the Site (“Rent”) shall be [***] per annum, payable in equal installments of [***] per month, adjusted upward every five (5) years thereafter during the Initial Term and during any Extended Term by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment during any Adjustment Period (as defined below) of greater than [***]. The period of time from the Ground Lease Commencement Date through the date five years thereafter, and each five (5) year period thereafter shall be defined herein as an “Adjustment Period.” Any upward

 

8


adjustment based on a CPI Percentage Increase (as defined below) to any payment under this Ground Lease shall hereinafter be referred to as a “CPI Adjustment.” Such Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month, provided however, that: (a) the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; and (b) the first payment of Rent due upon the commencement of any new Adjustment Period will be owed and paid one month after the commencement of that Adjustment Period and shall reflect the Estimated CPI Percentage Increase, if any.

4.2 CPI Adjustment. If CPI Percentage Increase (as defined below) is more than [***] for the relevant Adjustment Period, then the Rent payable during that Adjustment Period shall be adjusted upward by a percentage equal to the CPI Percentage Increase (as defined below) applicable to such Adjustment Period, but not to exceed an adjustment during any Adjustment Period of greater than [***]. The term “Consumer Price Index” shall mean the unadjusted Consumer Price Index for All Urban Workers, U.S. City Average, All Items, 1982-84= 100, calculated and published by the United States Department of Labor, Bureau of Labor Statistics. The “CPI Percentage Increase” shall mean, with respect to any Adjustment Period, [***]. For the avoidance of doubt, no CPI Adjustment shall be made to any payment due under this Ground Lease for any Adjustment Period if the result of such CPI Adjustment would be to (a) reduce the amount of such payment to an amount that is less than the amount of such payment due for the immediately preceding Adjustment Period or (b) to raise the amount of such payment to an amount that is greater than [***]. For illustrative purposes only, [***]. The CPI Percentage Increase for any Adjustment Period shall be calculated by the Tenant, and the Tenant shall deliver written notice to the Landlord describing such calculation in reasonable detail (a “CPI Notice”) no later than thirty (30) days after the commencement of any Adjustment Period. If the Landlord disagrees with the Tenant’s calculation of the CPI Percentage Increase, then the Landlord shall deliver to the Tenant written notice, describing the basis for such disagreement in reasonable detail (a “CPI Disagreement Notice”), not later than thirty (30) days after delivery of the CPI Notice. If the Landlord fails to deliver a CPI Disagreement Notice within thirty (30) days after delivery of any CPI Notice, then the Landlord shall be conclusively deemed to have agreed with the calculation of the CPI Percentage Increase set forth in such CPI Notice.

 

9


4.3 Due Date. Except as otherwise provided in this Ground Lease, all Rent payments shall be due in advance on the 1st calendar day of each month and payable by the 15th calendar day of each month during the entire term of this Ground Lease; provided, however, that the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month. If the 15th calendar day of a month falls on a weekend day or holiday, then Rent shall be payable on the following Business Day.

4.4 Place of Payment. Except as otherwise provided herein, Rent shall be payable by check or wire transfer at the following address or via wire instrnctions provided by the Landlord to the Tenant in writing, or to such other place as the Landlord may specify and the Tenant deem acceptable, as hereinafter provided, from time to time: [***].

5. Net Lease; Taxes and Utility Expenses.

5.1 Net Lease. This Ground Lease is a net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs, if any, of every kind and nature whatsoever relating to the Site except as expressly otherwise provided in this Ground Lease.

5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and Governmental Approval fees applicable to the Site during the term of this Ground Lease.

(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on or related to the Improvements and underlying real property comprising the Site during the term of this Ground Lease (prorated on the basis of a 365-day year to account for any fractional portion of a fiscal tax year included in at the commencement or expiration of the Term). . The Landlord shall promptly provide all Property Tax bills when they become available. Upon the latter of (i) one (1) month after receipt of such Property Tax bill from the Landlord or (ii) the due date of any such Property Taxes, the Tenant shall provide the Landlord with reasonable written evidence from the Cameron Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

(c) The Landlord shall provide written notice to the Tenant of its receipt of any oral or written notice of any audit, examination, claim or assessment relating to Property Taxes on or related to the Improvements within ten (10) Business Days following receipt of such notice. At the Tenant’s election, the Landlord shall initiate a claim and commence proceedings with the appropriate Governmental Authority to contest, resolve, appeal, defend and settle any such audit, examination, claim or assessment, as applicable, all at the Tenant’s direction and at the Tenant’s expense. The Landlord and the Tenant shall otherwise reasonably cooperate to minimize assessed value of the Improvements and underlying real property, including through coordination with the Cameron Parish Tax Collector’s Office.

 

10


5.3 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost, electricity, telephone, water, sewerage, gas:, and other utility services to the Site; provided, however, the Landlord shall cooperate, and to the extent reasonably needed, facilitate the contracting of any easements, servitudes and/or rights of way, and grant easements, servitudes and rights of way in accordance with Section 2.3, as required by the Tenant for such utility connections and/or services.

6. Tenant and Landlord Improvements.

6.1 Landlord’s Improvements. “Landlord’s Improvements” are any and all improvements to the immovable property of the Site and any and all movable property in existence on the Site at the time of the Ground Lease Commencement Date.

6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install on the Site, any Improvements during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. The Tenant shall be permitted to make any changes, improvements or alterations to the Site, including, without limitation, the Facilities and any Improvements to the Site, during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws.

6.3 Governmental Approvals. The Landlord will cooperate and assist (and never oppose) the Tenant in obtaining any and all Governmental Approvals deemed necessary by the Tenant for the Facilities and all other Improvements to the Site, including with respect to Governmental Approvals from the Federal Energy Regulatory Commission and the Department of Energy: provided, however Landlord will not be required to incur material costs or expenses in such efforts without reimbursement by the Tenant. The Landlord will hereafter continue to be obligated to execute appropriate documentation to waive its right to require wetlands mitigation to be completed on the Site or other real (immovable) property owned by the Landlord, in such form as necessary to allow the Tenant to complete such wetlands mitigation at locations other than other real (immovable) property owned by the Landlord.

6.4 Tenant’s Property. Tenant’s Property shall at all times be and remain the sole property of the Tenant.

6.5 Maintenance of Improvements.

(a) Tenant’s Obligation to Maintain. During the Initial Term or any Extended Term, as applicable, the Tenant will keep in reasonably good state of repair the Facilities, the Improvements, open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Site by the Tenant, and the Tenant will, in its sole discretion and cost, repair such property as often as may be necessary in order to keep the Facilities and the Improvements in reasonably good repair and condition, except as set forth in Section 6.5(b).

 

11


(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease:, the Landlord has no obligation to maintain the Site, Improvements and/or Landlord’s Improvements (if any) during the Initial Term and/or any Extended Term and shall have no obligation to fence any portion of the site or to secure any site boundary. The Landlord further agrees that there will be no Landlord improvements on the Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

7. Tenant’s Surrender of Site.

7.1 Surrender at End of Ground Lease. Subject to Section 6.4 and subject and subordinate to Section 23 and the rights of any Leasehold Lender under any Leasehold Mortgage:, the Tenant shall and will on the last day of the Initial Term:, or if extended, on the last day of the Extended Term hereof, surrender and deliver the Site to the Landlord, in good condition as is reasonably practicable (except as provided in Section 6.5 or Section 13), excepting normal wear and tear. If this Ground Lease is terminated for any reason or upon the expiration of the Initial Term and/or Extended Term (if extended) of this Ground Lease, the Tenant shall in good faith proceed with (i) any removal of the Facilities and any and all Improvements and (ii) restoration, if any, of the Site to its condition prior to construction of the Facilities and/or Improvements. The Tenant shall have all access rights to the Site that are necessary to remove any and all of the Tenant’s Property, including the Facilities and/or Improvements. The Tenant shall also comply as required by any federal regulations of the Federal Energy Regulatory Commission or any other federal authority with respect to the Facilities on the Site.

7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date the Tenant shall assume full dominion, control and responsibility for the Site, except to the extent specifically provided herein, to the extent provided under LSA - R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real (immovable) or personal (movable) property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its officers, representatives, agents, or employees or the Landlord’s misrepresentations or its breach of or default under this Ground Lease.

7.3 Holding Over. Except for a Removal Period, if the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, and shall not constitute a renewal or extension of the term of this Ground Lease.

 

12


8. Use.

8.1 Permitted Uses; Compliance with Laws; Permits. The Tenant may use the Site for any and all uses desired by the Tenant in compliance with all Applicable Laws. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the construction, operation, and maintenance of the Facilities, the Improvements and/or for the Tenant’s use or activities on the Site. The Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Facilities, the Improvements, and the security of the Site, including the timely filing, implementation, and enforcement of any security plan required by Applicable Laws. Any fine or penalty imposed by any Governmental Authority solely caused by the failure of the Tenant to comply with this provision, including any fine or penalty imposed upon the Landlord as owner of the Site as solely caused by the failure of the Tenant to comply with this provision,, shall be the sole responsibility of the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall indemnify and hold harmless the Landlord from the payment of any such fine or penalty, and the Tenant may pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord.

8.2 Dirt Moving Activities; Permits; Timber.

(a) The Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Site, to the Site, and from portions of the Site to other portions of the Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Site and may do so in its discretion. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Site, including without limitation, for any Improvements, reclamation of lands, erosion control, attainment of spoil, easements/servitudes and/or rights of way; provided, that all costs associated with such efforts shall be the responsibility of the Tenant; provided, such activities are at Tenant’s cost and expense. Except only as provided in Section 8.2(b). the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Site, and all other rights on and to the Site. Any activities of the Landlord and/or its lessees or assignees or any other party shall not adversely affect the Site or the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any way. Nothing herein is intended to preclude the Landlord, from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation. The Tenant may freely remove any timber which is standing or lying on the Site as the Tenant deems necessary for the Tenant’s intended use of the Site. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights below the surface of the Site.

(b) To the extent the Landlord holds any rights to oil, gas, or other minerals (“Minerals”) in the Site, the Landlord waives any and all rights of the Landlord or its lessees or assignees to use the surface of the Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the term of this Ground Lease, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means

 

13


consistent with the terms and conditions of this Section 8.3 (b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any way.

8.4 Crossing. The Landlord shall assist the Tenant in the Tenant’s efforts to develop, at the Tenant’s cost, any roads and/or crossings or other Improvements across the Site and boundary lines of the Site to the adjacent land, including relocation of utilities, providing culverts for storm water drainage, and any other Improvements. The Tenant or others, excluding the Landlord, will pay the cost to relocate or modify the infrastructure for these roads and/or crossings and/or other Improvements.

8.3 Access License Agreement. The Landlord hereby consents to the Tenant providing to the Tenant’s Affiliates non-exclusive access to the Site pursuant to one or more access license agreements with its applicable Affiliates; provided that the foregoing shall not serve to modify or limit any of the Landlord’s or the Tenant’s rights and obligations under, or the terms and conditions of, this Ground Lease. Upon Leasehold Lender’s or Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate consenting to such access and related access rights agreements.

9. Indemnification.

9.1 Tenant’s General Agreement to Indemnify. The Tenant releases the Landlord, its officers, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, witness fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Landlord lndemnitee arising out of (i) the use or occupancy of the Site by the Tenant, its officers, representatives, agents, and employees, (ii) the construction or operation of the Facilities by the Tenant, its officers, representatives, agents, and employees, (iii) any claim arising out of the use, occupancy, construction or operation of the Site by the Tenant, its officers, representatives, agents, and employees, and (iv) activities on or about the Site by the Tenant, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, operation, maintenance, or repair of the Site, the Facilities, or the Improvements, by the Tenant, its officers, representatives, agents, and employees; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Landlord lndemnitee shall be excluded from this indemnity. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9.2 and 9.4 and not this Section 9.1.

 

14


9.2 Tenant’s Environmental Indemnification. For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with all Environmental Laws applicable to the Tenant, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Tenant agrees to indemnify and hold harmless the Landlord Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorney, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth above in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Site or any violation of any Environmental Law with respect to the Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, and maintenance activities or facilities and not caused by the Landlord’s Activities or Landlord’s Improvements.

9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Site by the Landlord, its officers, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Site by the Landlord, its officers, representatives, agents, and employees, and (iii) activities on or about the Site by the Landlord, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope but not be limited to any and all claims or actions for wrongful death, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.4 and not this Section 9.3.

9.4 Landlord’s Environmental Indemnification.

For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorneys, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person

 

15


(including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (a) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances; (b) any actual or alleged violation of Environmental Laws, in the case of each of subclauses (a) and (b), where the presence, discharge or release of such Hazardous Substances or violation of Environmental Law arises or occurs (i) at, on or from the Site on or prior to the Ground Lease Commencement Date or (ii) at, on or from the Site or any other site as a result of or relating to the Landlord’s Activities or facilities or Landlord’s Improvements, whether before, on or after the Ground Lease Commencement Date; (c) the Landlord’s breach of the covenant set forth above in this Section 9.4; or (d) any environmental condition of contamination on the Site or any violation of any Environmental Law with respect to the Site to the extent occurring after the Ground Lease Commencement Date and caused by the Landlord’s Activities or facilities.

9.5 Survival of Indemnities. The foregoing indemnities shall survive the Initial Term, any Extended Term and any Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

10. Insurance.

10.1 Tenant Insurance. The Tenant shall carry or cause to be carried commercial general liability insurance with respect to the Site and the uses and activities of the Tenant thereon with minimum limits of [***]. The Tenant may elect to be self-insured in amounts greater than those minimum limits. In the event the Tenant procures commercial general liability insurance, the Landlord will be named as an additional insured.

10.2 Landlord Insurance. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Site and/or any activities of the Landlord with respect to the Site in its reasonable business discretion. The Landlord may elect to be self-insured.

11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. The Landlord shall not create or permit to be created or to remain in connection with the Site, or the Facilities, the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Site or upon the Landlord’s interest in the Site or upon the Tenant’s interest in its leasehold of the Site, in accordance with Section 11.2.

 

16


11.2 Discharge of Liens.

(a) If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

(b) If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such Lien by deposit or by bonding proceedings. Any amount so paid by the non-responsible Party and all costs and expenses incurred by the non-responsible Party in connection therewith, including reasonable attorneys’ fees together with interest thereon at one percent (1%) per annum above the Wall Street Journal Prime Rate of interest published from time to time in the Wall Street Journal, from the respective dates of the non-responsible Party’s making of the payment or incurring of the cost and expense, shall constitute either additional rent payable by the Tenant under this Ground Lease or an offset against Rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Site, including without limitation, any liabilities, obligations and/or debts owed to laborers, vendors, brokers, materialmen, and other service providers, and then offset against the Rent any such amount(s) paid by the Tenant.

12. Entry on Premises by Landlord, Etc.

 

The Landlord and its representatives shall have no right to enter the Site, except as specifically authorized from time to time in advance in writing by the Tenant after written notice to the Tenant of such request by the Landlord; and such authorization shall be in the Tenant’s sole discretion, and if/when granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of the Tenant. Such entry on the Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions such that access to certain sections of the Site will be restricted.

 

17


13. Destruction by Fire or Other Casualty.

If the Facilities or any Improvements erected on the Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the willful misconduct of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Facilities or the Improvements. In the event that the Tenant so decides not to restore or reconstruct the Facilities or the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove any ruins or rubble remaining on the Site at the Tenant’s sole cost and expense.

14. Assignment; Subleasing; Right of First Refusal.

14.1 Restrictions on Landlord. The Landlord shall not assign this Ground Lease or sell the Site, in whole or in part, (including without limitation by transfer of control or otherwise) without the prior written consent of the Tenant, except with respect to the Tenant’s right of first refusal as set forth in Section 14.3. This Ground Lease shall inure to the benefit of and shall be binding upon the Landlord’s permitted assigns.

14.2 Restrictions on Tenant. Subject to the provisions of Section 23, the Tenant shall not assign this Ground Lease, in whole or in part, without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least thirty (30) days prior written notice of any proposed assignment, together with a copy of the proposed assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing, including to a Leasehold Lender, (ii) to a Leasehold Lender or any purchaser upon a foreclosure of a Leasehold Mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a Leasehold Mortgage, (iii) to any Affiliate or member of the Tenant, (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder. The Tenant shall not sublease all or any portion of the Site without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned.

14.3 Right of First Refusal. During the Initial Term or any Extended Term of this Ground Lease, the Landlord may not transfer a portion of the Site and may only transfer the entire Site through a bona fide sale in exchange for a sum certain of money. If the Landlord, during the Initial Term or any Extended Term of this Ground Lease, makes a bona fide offer to sell or receives a bona fide offer from a third party to buy or acquire (individually and collectively a “Bona Fide Offer”) all or any portion of the Site separately or as a part of a larger parcel of which the Site is a part, the Landlord will promptly, within ten (10) Business Days of such making or receipt, give written notice to the Tenant of the terms of the Bona Fide Offer made or received, including the cash price attributable to the Site. If the sale is a tract of which the Site is a part, then the cash price attributable to the Site will be that part of the cash price multiplied times a fraction, the denominator of which is the total number of acres in the Site and the numerator of which is the

 

18


total number of acres in the larger tract to be sold. The notice shall also state the other terms and conditions of the proposed sale and the Landlord’s willingness to sell for that cash price and on those terms. Upon receiving the notice, the Tenant may exercise the right, in the manner specified below, to purchase either the property described in the Bona Fide Offer or the Site (or part thereof) at the lower of: (i) the stated cash price in the Bona Fide Offer or (ii) Fair Market Value, which shall not include any value of this Ground Lease, the Facilities, the Improvements and/or Landlord’s Improvements in the determination of the Fair Market Value, pursuant to the process described in Sections 14.3 through 14.6. This Section 14.3 does not apply to transfers pursuant to successions or donations executed in accordance with Louisiana law.

14.4 Exercise of Right of First Refusal. If the Tenant elects to purchase the property or Site described in the Bona Fide Offer under the provisions of Section 14.3, or if the Tenant elects to seek the Fair Market Value under the provisions of Section 14.3, the Tenant must notify the Landlord of such election, doing so in writing delivered to the Landlord within thirty (30) Business Days after the date of the Landlord’s written notice to the Tenant of the Bona Fide Offer. If the Tenant elects to refuse the Bona Fide Offer, the Tenant need take no action whatsoever; further, if the Tenant fails to deliver to the Landlord a notice of the Tenant’s election within the time required for such notice, the Tenant will be deemed to have refused the Bona Fide Offer. If the Tenant refuses, or is deemed to have refused, the Bona Fide Offer, the Landlord is free to sell the property pursuant to the Bona Fide Offer subject to this Ground Lease, any New Lease, and any Leasehold Mortgage, any Non-Disturbance Agreement and continuation of the leasehold interest created by this Ground Lease and any New Lease.

14.5 Fair Market Valuation. If the Tenant elects to seek the Fair Market Value under the provisions of Section 14.3, then the Tenant shall notify the Landlord of the Tenant’s proposed Fair Market Value for the property or the Site, as the case may be. Thereafter, for a period of thirty (30) days following such notice the Parties shall in good faith attempt to agree upon the Fair Market Value. If the Parties do not agree upon the Fair Market Value within such thirty (30) days, each of the Parties shall within the next thirty (30) days appoint a qualified appraiser to appraise the Fair Market Value (the “First Appraiser” and the “Second Appraiser”) by notice to the other Party. If the Second Appraiser is not timely designated, the determination of the Fair Market Value shall be made solely by the First Appraiser. The First Appraiser, or each of the First Appraiser and the Second Appraiser if the Second Appraiser is timely designated, shall submit its determination of the Fair Market Value to the Parties within thirty (30) days of the date of its selection (or the selection of the Second Appraiser, as applicable). If there are two (2) appraisers and their respective determinations of the Fair Market Value vary by less than ten percent (10%) of the higher determination, the Fair Market Value shall be the average of the two determinations. If such determinations vary by ten percent (10%) or more of the higher determination, the two appraisers shall promptly designate a third appraiser (the “Third Appraiser”). Neither the Tenant nor the Landlord shall provide, and the First Appraiser and Second Appraiser shall be instructed not to provide, any information to the Third Appraiser as to the determinations of the First Appraiser and the Second Appraiser or otherwise influence such Third Appraiser’s determination in any way. The Third Appraiser shall submit its determination of the Fair Market Value to the Parties within thirty (30) days of the date of its selection. The Fair Market Value shall be equal to the average of the two closest of the three determinations. The determination of the Fair Market in accordance with the foregoing procedure shall be final and binding on the Parties. If any appraiser is only able to provide a range in which Fair Market Value would exist, the average of

 

19


the hlghest and lowest value in such range shall be deemed to be such appraiser’s determination of the Fair Market Value. Each appraiser selected pursuant to the provisions of this Section 14.5 shall be a qualified Person with prior experience in appraising industrial lands in south Louisiana and that is not an interested Person with respect to either Party or such Party’s Affiliates. If the Tenant has invoked this process and when the Fair Market Value has been determined, then the Tenant must notify the Landlord in writing within thirty (30) days that the Tenant elects to purchase the property or Site at the lower of either the Fair Market Value determined or the Bona Fide Offer; and if the Tenant fails to notify the Landlord within this thirty (30) day period, then the Landlord is free to sell the property or Site pursuant to the Bona Fide Offer subject to this Ground Lease and any Leasehold Mortgage, any New Lease and any Non-Disturbance Agreement, and continuation of the leasehold interest created by this Ground Lease.

14.6 Continuation of Right. If for any reason the Site is not sold by the Landlord following a Bona Fide Offer from a third-party, the right of first refusal granted and described in the preceding Sections 14.1 through 14.5 shall continue in full force and effect, on the same terms and conditions.

15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of fifteen (15) days after written notice thereof from the Landlord to the Tenant.

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15. l (a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Site or discharge from the Site shall not constitute an Event of Default.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages; Termination. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default, the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the Tenant shall be liable for such reasonable damages unless such Event of Default is reasonably remedied in a timely manner and

 

20


all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default, together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and payable, and all costs and expenses reasonably incurred by or on behalf of the Landlord as a result of the Event of Default, including reasonable attorneys’ fees, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective and is not valid if the Landlord does not give prior written notice to the Tenant pursuant to Section 15.1.

(b) Landlord’ s Right to Cure Tenant’ s Event of Default. Upon the occurrence of an Event of Default of the Tenant which is not cured or having commenced curing by the Tenant within sixty (60) days as provided in Section 15.2(b), then, subject to the prior written consent of any Leasehold Lender under Section 23, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others to cure the Event of Default. The Tenant shall be responsible for all costs, including attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord.

(c) Sole Recourse. The sole recourse of the Landlord for any damages or liabilities due hereunder shall be limited to the assets of the Tenant, without recourse individually or collectively to the assets of the members or the affiliates of the Tenant, its lenders, or their respective directors, agents, members, shareholders, managers, employees, representatives, partners, and officers.

15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Site to the Landlord, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Site and may have, hold, and enjoy the Site; and (ii) all obligations of the Tenant hereunder for additional rent or any portion thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. If the Landlord obtains a successor tenant during what would have been the remainder of the term of this Ground Lease, the Tenant shall receive a credit for rentals collected from said successor tenant for the remaining term of this Ground Lease. If no successor tenant is obtained, the Tenant shall be liable for Rent obligations otherwise provided for in this Ground Lease.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

 

21


16. Events of Default of the Landlord.

16.1 Landlord’s Event of Default; Right to Cure. Any failure of the Landlord to perform and/or to comply with any of its obligations, covenants, agreements, terms, or conditions contained in this Ground Lease shall constitute a “Landlord’s Event of Default” hereunder. The Landlord shall have sixty (60) days after notice by the Tenant to the Landlord of Landlord’s Event of Default to fully cure Landlord’s Event of Default.

16.2 Tenant’s Remedies; Cure. In the event of a Landlord’s Event of Default that is not fully cured under Section 16.1, in addition to all other remedies available to the Tenant, the Tenant may cancel this Ground Lease by written notice to the Landlord. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof, and shall be immediately payable to the Tenant. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default that is not fully cured under Section 16.1.

16.3 Tenant’s Right to Cure Landlord’s Event of Default. Upon the occurrence of a Landlord’s Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord’s Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others, purchasing the required goods or services and procuring necessary insurance. The Landlord shall be responsible for all costs including attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

17. Mutual Obligations.

17.1 Late Charges; Interest. If any Rent or other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of fifteen (15) days after receipt of written notice, such sum shall bear a late charge equal to one percent (1.0%) of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

 

22


17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise (excluding, however, specific performance against the Tenant) and the exercise or beginning of the exercise by the Parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by email or United States registered or certified mail, return receipt and signature requested, postage prepaid, to the Parties at the following numbers and addresses:

 

         To the Tenant:    Venture Global CP2 LNG, LLC
     1001 19th St North
     Suite 1500
     Arlington, VA 22209
     Attention: [***]
     Email: [***]
     Venture Global CP2 LNG, LLC
  With a copy to:    1001 19th St North
     Suite 1500
     Arlington, VA 22209
     Attention: [***]
     Email: [***]

 

23


  To the Landlord:    Ardoin Henry, LLC
     1332 W. Jefferson Drive
     Attention: [***]
     Email: [***]
     And
     134 World of Tennis Square, Austin, TX 78738
     Attention: [***]
     Email: [***]
  With a copy to:    Jeff E. Townsend, Jr.
     Attorney at Law
     P.O. Box 1463
     Lake Charles, LA 70602-1463
     Email: [***]
     And
     Stockwell, Sievert, Viccellio, Clements & Shaddock, LLP
     Attn.: [***]
     P.O. Box 2900, Lake Charles, LA 70602-2900
     Email: [***]

or to such other numbers or addresses as either above designated recipients may from time to time designate by written notice to the other designated recipient hereto at least fifteen (15) days in advance of an effective date stated therein.

18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mait return receipt and signature requested, postage prepaid.

19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable possession of the Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Site during the Initial Term, any Extended Term and any Removal Period of this Ground Lease without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord. This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow compatible use of the remainder of their property adjacent to the Site and will not create or allow the creation of a visual, olfactory or auditory nuisance on said remainder of their property.

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that: (i) it is the sole owner of good title to all of the Site; (ii) to the best of its information and belief the Site is subject to no Liens, privileges, encumbrances, defects in title, servitudes, easements, restrictions, dedications, leases, mineral leases, reservations or other exceptions to title; (iii) during the term hereof it shall not encumber the Site; (iv) it is authorized to make this Ground Lease for the term hereof; (v) the provisions of this Ground Lease do not will not conflict with or violate any of the provisions of existing agreements between the Landlord and any third party; and (vi) the Landlord will deliver the Site free of all tenants and occupants and claims thereto.

 

24


20. Eminent Domain.

20.1 Complete Condemnation. If, during the term hereof, the whole of the Site shall be taken under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking) by any public or private authority, then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided that the Tenant shall share in the condemnation award as provided herein. The Tenant may continue to occupy the Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Site from and after the date of such taking.

20.2 Partial Condemnation. If, during the term hereof, any public or private authority shall, under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking), makes a taking resulting in the reduction of the surface area of the Site by fifteen percent (1 5%) or more, or of fifteen percent ( 1 5%) or more of the value of the Facilities, the Improvements or the Landlord’s Improvements, or resulting in material interference to the Tenant’s ability to use in a commercially reasonable manner the remainder of the Site, the Facilities, the Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of the exercise of its election within one-hundred twenty (1 20) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2, the term hereof shall cease and terminate as of the last day of the calendar month in which such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant, and the Tenant shall share in the condemnation award as provided herein.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the term hereof shall continue in full force and effect, and the monthly Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete taking pursuant to Section 20.1, the Tenant will be entitled to receive the portion of the condemnation award (or settlement) attributable to (i) the value of the Facilities, the Improvements, and Landlord’s Improvements, and fixtures and other property located on the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, plus (iii) other compensation or benefits paid as a consequence

 

25


of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking (if any such compensation or benefits are paid by the applicable taking authority) and the Landlord shall be entitled to recover that portion of the condemnation award (or settlement) fairly attributable to the value of the land taken. In the event Tenant’s Property, the Improvements, or the Facilities are not taken, the Tenant shall not be entitled to any portion of the award. In the event of a partial taking of the Improvements, the Tenant’s Property and/or Facilities, the entire award or settlement shall be paid to the Tenant. In the event of a partial taking of the Site, the Tenant will be entitled to receive the portion of the award attributable to (i) the value of the portion of the Facilities, Improvements and Tenant’s Property located in the portion of the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, plus (iii) damage to the remaining Facilities, and the Tenant will promptly restore the remaining portion of the Facilities to the extent of the award payable to the Tenant. Nothing contained herein shall prohibit the Tenant’s claiming relocation damages or damages for lost profits or loss of leasehold advantage against the taking authority in any appropriate proceeding.

21. Temporary Taking or Other Deprivation.

If, during the term hereof, (i) less than all of the Landlord’s title to all or any portion of the Site is taken for temporary use or occupancy, or (ii) any public or private authority takes any action not resulting in a taking of all or any portion of the Site but resulting in a right to compensation therefor, such as changing of the grade of any street upon which the Site abuts, then, except as otherwise provided in Section 20, the Tenant shall be entitled to make claim for, recover, and retain all awards, whether pursuant to judgment, agreement, or otherwise, recoverable in connection therewith.

22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure; provided that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section shall govern and control.

 

 

26


23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage, or any agent or trustee therefor, that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant. The term “Leasehold Mortgage” shall mean, at any point in time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Site and this Ground Lease. It is acknowledged and agreed that, during the term of this Ground Lease, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the term of this Ground Lease, the Tenant shall provide the Landlord with written notice of the identity, contact information and address for each Leasehold Lender (or the agent authorized to act on behalf of the Leasehold Lender), such notice to be provided to the Landlord by the Tenant within no less than a calendar year within which the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

23.2 Right to Perform for Tenant; Right to Cure.

(a) In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and the Landlord shall accept such performance by Leasehold Lender with the same force and effect as if furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing.

(b) If any default in the performance of an obligation of the Tenant under this Ground Lease is not susceptible to being cured by Leasehold Lender, the Landlord shall have no right to terminate this Ground Lease with respect to such default and such default shall be deemed waived for the benefit of Leasehold Lender only, provided that:

(i) Leasehold Lender shall have commenced to cure (i) any other non-payment default of the Tenant that is susceptible to being cured by Leasehold Lender and (ii) any default in the payment of any portion of Rent, in each case, within the time periods prescribed under Section 23.2(a):

(ii) Leasehold Lender (or its designee) shall have commenced to acquire the Tenant’ s interest in this Ground Lease and the Site or to commence foreclosure or other appropriate proceedings under the Leasehold Mortgage within the time periods prescribed under Section 23.2(a);

 

27


(iii) if Leasehold Lender (or its designee) shall acquire the Tenant’s interest in this Ground Lease and/or the Site, Leasehold Lender (or its designee) shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition; and

(iv) if any third party shall, by foreclosure or dation en paiement under the Leasehold Mortgage or by assignment or other transfer from Leasehold Lender, acquire the Tenant’s interest in and to the Site under this Ground Lease, such third party shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by a third party with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition.

However, if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23 .2 within the applicable time periods set forth in Section 23.2, then notwithstanding any provision in this Section 23 to the contrary, the Landlord may exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’s prior written consent, and any such action taken without Leasehold Lender’s consent shall not be binding on the Tenant or Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23 .2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.4 Deliverv of Notices. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including, without limitation, any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been delivered to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in writing to the

 

28


Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’ s interests in the Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including, without limitation, the acquisition of the Tenant’s interest in this Ground Lease and the Site created thereby in a transaction described in this Section 23 or the taking of possession of the Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender; provided that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Site.

23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2, the purchaser at any sale of this Ground Lease and the interests in and to the Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including, without limitation, power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Site thereby created under any instrument of assignment or transfer in lieu of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Site thereby created.

 

29


23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, substantially all, or any part of the Site or the Tenant’s Facilities. Rent shall continue to be due and payable as set forth in this Ground Lease.

23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent domain proceeding of all, substantially all, or any part of the Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Facilities, the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Site created by this Ground Lease and the value of the leasehold improvements located on the Site, up to an amount equaling the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Facilities and/or the Tenant’s interest in, under and to this Ground Lease; provided that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under applicable law to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this Ground Lease. In the event of a taking of a portion of the Site, the Rent shall be reduced pro rata based upon the portion of the Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease.

23.9 New Direct Lease.

(a) If this Ground Lease is canceled or terminated for any reason (except in connection with a Bankruptcy Proceeding, for which the provisions of Section 23.10 are hereby agreed upon by the Landlord and the Tenant), and provided that Leasehold Lender has (i) commenced to cure and continues diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, and (ii) cured any payment default in respect of any portion of Rent, the Landlord hereby agrees that the Landlord shall, upon Leasehold Lender’s written election within one hundred twenty (120) days of such cancellation or termination, promptly enter in a new, direct lease with Leasehold Lender (or its nominee or any other party which Leasehold Lender may designate, including without limitation, the Tenant) with respect to the Site on the same terms and conditions as this Ground Lease (a “New Lease”), it being the intention of the parties to preserve this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Said New Lease shall be superior to all rights, liens and interests intervening between the date of this Ground Lease and the granting of the New Lease and shall be free of any and all rights of the Tenant under this Ground Lease.

 

30


(b) The Tenant and the Landlord acknowledge and agree that Leasehold Lender shall have the right to encumber such direct New Lease and the estate created thereby with a deed of trust or a mortgage (as the case may be) on the same terms and with the same lien priority as the Leasehold Mortgage, it being the intention of the parties to preserve the priority of the Leasehold Mortgage, this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. If this Ground Lease is rejected, cancelled or terminated for any reason and Leasehold Lender, its nominee or a designee of Leasehold Lender enters into a direct lease with the Landlord with respect to the Site, the Landlord hereby agrees that it will execute such documents as Leasehold Lender may require in order to ensure that the new direct lease provides for customary leasehold mortgagee protections, including without limitation, protections similar to those contained herein.

23.10 Bankruptcy. In the event of a proceeding under the United States Bankruptcy Code (Title 11 U.S.C.) as now or hereafter in effect (a “Bankruptcy Proceeding”):

(a) If this Ground Lease is rejected in connection with a Bankruptcy Proceeding by the Tenant or a trustee in bankruptcy (or other party to such proceeding) for the Tenant, such rejection shall be deemed an assignment by the Tenant to the Leasehold Lender of the Tenant’s Property and all of the Tenant’ s interest under this Ground Lease, and this Ground Lease shall not terminate and the Leasehold Lender shall have all rights and obligations of the Tenant as if such Bankruptcy Proceeding had not occurred, unless Leasehold Lender shall reject such deemed assignment by notice in writing to the Landlord within thirty (30) days following rejection of this Ground Lease by the Tenant or the Tenant’s trustee in bankruptcy. If any court of competent jurisdiction shall determine that this Ground Lease shall have been terminated notwithstanding the terms of the preceding sentence as a result of rejection by the Tenant or the trustee in connection with any such proceeding, the rights of Leasehold Lender to a New Lease from the Landlord pursuant to Section 23 .9 hereof shall not be affected thereby.

(b) In the event of a Bankruptcy Proceeding against the Landlord:

(i) If the bankruptcy trustee, the Landlord (as debtor-in-possession) or any party to such Bankruptcy Proceeding seeks to reject this Ground Lease pursuant to United States Bankruptcy Code §365(h)(l), the Tenant shall not have the right to treat this Ground Lease as terminated except with the prior written consent of Leasehold Lender and the right to treat this Ground Lease as terminated in such event shall be deemed assigned to Leasehold Lender, whether or not specifically set forth in the Leasehold Mortgage, so that the concurrence in writing of the Tenant and the Leasehold Lender shall be required as a condition to treating this Ground Lease as terminated in connection with such Bankruptcy Proceeding.

(ii) Unless this Ground Lease is treated as terminated in accordance with Section 23.10(b)(i), then this Ground Lease shall continue in effect upon all the terms and conditions set forth herein, including Rent, but excluding requirements that are not then applicable or pertinent to the remainder of the term of this Ground Lease. Thereafter, the Tenant or its successors and assigns shall be entitled to any offsets against Rent payable hereunder for any

 

31


damages arising from such bankruptcy, to the extent the Tenant’s operation of business has been materially interfered with, and any such offset properly made shall not be deemed a default under this Ground Lease. The lien of the Leasehold Mortgage shall extend to the continuing possessory rights of the Tenant following such rejection with the same priority as it would have enjoyed had such rejection not taken place.

23.11 Estoppel Certificates; Non-Disturbance Agreements.

(a) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel”) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under this Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant thereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that each of this Ground Lease and the Non-Disturbance Agreement, true, correct copies of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, have not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Landlord’s power and authority to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, and any Non-Disturbance Agreement, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which Landlord is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the Landlord Estoppel, the present lessor under this Ground Lease and owns good and indefeasible title to the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Site, and has not agreed

 

32


with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (xix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

(b) Within fifteen (15) days following Leasehold Lender’s or the Landlord’s written request, the Tenant shall provide Leasehold Lender with an estoppel certificate (the “Tenant Estoppel”) which shall certify to such requesting Leasehold Lender (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Landlord of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Landlord of any other conditions required under this Ground Lease, (iii) as to any existing default of the Landlord under this Ground Lease, or alternatively that the Landlord is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Landlord hereunder, and as to any existing event or condition in existence as of the date of the Tenant Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Tenant to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Tenant, (v) that this Ground Lease, a true and correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Tenant’s power and authority to execute the Tenant Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Tenant asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Tenant from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties, or other sums, whether or not constituting rent, due and owing as of the date of the Tenant Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which the Tenant is a party (other than those set forth on a schedule to the Tenant Estoppel), (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Tenant Estoppel, (xiv) that the Tenant is, as of the date of the Tenant Estoppel, the present 

 

33


lessee under this Ground Lease and holds a valid leasehold interest in the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Tenant has not assigned, sublet, hypothecated, leased, or otherwise transferred it interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Tenant’s interest in the Site, other than those set forth on a schedule to the Tenant Estoppel, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Tenant is a party or by which the Tenant is otherwise bound affecting the Tenant’s interest in and to the Site, (xvii) that the Tenant has not commenced any action or sent any notice to the Landlord for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Tenant is not, as of the date of the Tenant Estoppel, entitled to terminate, cancel, modify, or surrender this Ground Lease, and (xviii) as to such other matters related to this Ground Lease as such Leasehold Lender may reasonably determine from time to time.

(c) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall enter into a non-disturbance agreement with Leasehold Lender or its designee, in the form attached hereto as Exhibit 5 (a “Non-Disturbance Agreement”).

23.12 No Termination by Confusion. There shall be no termination by confusion of this Ground Lease or any interest in this Ground Lease or of the interests in and to the Site created thereby with the fee estate in the Site, by reason of the fact that this Ground Lease or such interest therein, may be directly or indirectly held by or for the account of any person who shall hold any interest in the fee estate in the Site, nor shall there be a merger by reason of the fact that all or any part of the interests in and to the Site created by this Ground Lease may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any interest in the fee estate in the Site or any interest of the Landlord under this Ground Lease.

23.13 Landlord’s Recognition of Tenant. The Landlord hereby recognizes the Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that the Tenant acquired its interest in this Ground Lease and in and to the Site in accordance with the terms of this Ground Lease.

23.14 Agreement to Amend. The Landlord recognizes the importance of the Tenant’s ability to obtain Leasehold Mortgages, and that the provisions of this Ground Lease may be subject to the approval of a Leasehold Lender. If any Leasehold Lender should require, as a condition to such financing, any reasonable modifications of this Ground Lease, whether for purposes of clarifying the provisions of this Ground Lease or to include provisions then customary for leasehold financing transactions, the Landlord agrees to execute the appropriate amendments to this Ground Lease; provided, however, that no such modification shall, to the detriment of the Landlord, impair any of the Landlord’s rights, as reasonably determined by the Landlord or increase any of the Landlord’s obligations, as reasonably determined by the Landlord, under this Ground Lease.

23.15 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

 

34


23.16 Subordination of Landlord’s Lien. The Landlord hereby subordinates any lien or privilege it may have on any movables found from time to time in or upon the Site, including without limitation, the Landlord’s privileges pursuant to La. Civil Code articles 2707, et seq., to any Leasehold Lender’s rights under this Section 23 and the lien of any Leasehold Mortgage.

24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

24.2 Successors. The covenants, agreements, terms, prov1s10ns, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties hereto.

24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

24.6 No Oral Change or Termination. This Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties hereto with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

 

35


24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

24.9 Litigation. In case of any litigation between the Parties hereto regarding the subject matter hereof, the losing Party shall pay all reasonable costs and expenses (including reasonable attorneys’ fees) of the prevailing Party. The venue of any litigation shall be solely in Cameron Parish.

24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

24.11 Authority. Each of the Landlord and the Tenant represents and warrants that it has the authority to enter into this Ground Lease, that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date, (a) the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 3, evidencing its authority to execute and perform under this Ground Lease and (b) the Landlord shall deliver to the Tenant a resolution in the form attached hereto as Exhibit 4, evidencing its authority to execute and perform under this Ground Lease.

24.12 Brokers and/or Real Estate Agents. Each of the Landlord and the Tenant represents, acknowledges and agrees that it is not represented by any real estate broker/agent and that it is not responsible for payment of any commissions to any real estate brokers/agents in connection with this Ground Lease.

24.13 Legal Relationships: Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. There is no third party beneficiary of this Ground Lease, except as provided in Section 23.15 and any rights of a Leasehold Lender as provided herein. This Ground Lease is the product of the Parties joint negotiation and equal drafting thereof. The language of this Ground Lease shall be construed as a whole according to its fair meaning and not construed strictly for or against any of the Parties pursuant to any statue, case law or rule of interpretation or construction to the contrary.

24.14 Further Assurances. In connection with this Ground Lease and the transactions contemplated hereby, each Party shall execute and deliver any additional documents and instruments and perform any additional acts that may be necessary or appropriate to effectuate and perform the provisions of this Ground Lease and those transactions, including in connection with the requests of any Financing Parties or Leasehold Lender.

 

36


24.15 No Waiver or Surrender. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Site and no agreement to accept a surrender of the Site shall be valid unless it is in writing and signed by the Landlord.

24.16 Memorandum of Lease. The Parties hereto agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’s interest hereunder; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease.

[Remainder of page left intentionally blank; signatures on following pages]

 

37


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

/s/ Jonathan M. Robillard

WITNESS Jonathan M. Robillard

      LANDLORD:
         ARDOIN HENRY, LLC

/s/ Derek H Hoffman

      By:   

/s/ Jacqueline Henry Adkins

WITNESS Derek H Hoffman       Name:    Jacqueline Henry Adkins
      Title:    Co-Manager

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Calcasieu and State of Louisiana, personally came and appeared Jacqueline Henry Adkins, who, after being sworn by me, did execute this agreement on the 12th day of October, 2023 at Lake Charles, State of Louisiana.

 

/s/ Steven D. Polito

NOTARY PUBLIC

 

1


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

/s/ Jonathan M. Robillard

WITNESS Jonathan M. Robillard

      LANDLORD:
      ARDOIN HENRY, LLC

/s/ Theresa A Barnatt

         By:   

/s/ Jan Ardoin Fontenor

WITNESS Theresa A Barnatt       Name: Jan Ardoin Fontenor
      Title: Co-Manager

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Calcasieu and State of Louisiana, personally came and appeared Jan Ardoin Fontenor, who, after being sworn by me, did execute this agreement on the 12th day of October, 2023 at Lake Charles, State of Louisiana.

 

/s/ Amy E. Donovan

NOTARY PUBLIC

 

1


     TENANT:

/s/ Tracy Pelt

    
WITNESS Tracy Pelt      VENTURE GLOBAL CP2 LNG, LLC
         By:   

/s/ Keith Larson

/s/ Jeff Layman

     Name: Keith Larson
WITNESS Jeff Layman      Title: Secretary

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 6th day of October, 2023 at Arlington, State of Virginia.

 

/s/ Michael Eliezer Millan

NOTARY PUBLIC

 

1


LIST OF EXHIBITS

 

Exhibit 1    Legal Description of the Site
Exhibit 2    Site Survey
Exhibit 3    Tenant’s Resolution
Exhibit 4    Landlord’s Resolution
Exhibit 5    Form of Non-Disturbance Agreement

 

1


EXHIBIT I

LEGAL DESCRIPTION OF THE SITE

PARCEL “P”

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND A HALF INCH DIAMETER IRON PIPE; THENCE 5.00°36’56"W., A DISTANCE OF 922.52 FEET TO THE NORTHEAST CORNER OF SECTION 34, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND THREE QUARTER INCH DIAMETER IRON PIPE, SAID POINT BEING THE POINT OF BEGINNING; THENCE S.00°36’40"W., A DISTANCE OF 908.19 FEET TO THE SOUTHEAST CORNER OF SAID SECTION 34, SAID POINT BEING MARKED BY A FOUND ONE INCH DIAMETER IRON BAR; THENCE S.00°36’51"W., A DISTANCE OF 85.42 FEET TO A POINT ALONG THE RIGHT DESCENDING BANK LINE OF THE CALCASIEU RIVER; THENCE N.81°19’30"W. ALONG SAID BANK LINE, A DISTANCE OF 86.18 FEET; THENCE S.84°59’13"W. ALONG SAID BANK LINE, A DISTANCE OF 59.34 FEET; THENCE S.89°35’47"W. ALONG SAID BANK LINE, A DISTANCE OF 86.18 FEET; THENCE S.84°59’13"W. ALONG SAID BANK LINE, A DISTANCE OF 59.34 FEET; THENCE S.89°35’47"W. ALONG SAID BANK LINE, A DISTANCE OF 24.54 FEET; THENCE S.84°30’10"W. ALONG SAID BANK LINE, A DISTANCE OF 49.56 FEET; THENCE S.77°57’22"W. ALONG SAID BANK LINE, A DISTANCE OF 24.17 FEET; THENCE S.83°39’05"W. ALONG SAID BANK LINE, A DISTANCE OF 19.93 FEET; THENCE S.79°03’31 "W. ALONG SAID BANK LINE, A DISTANCE OF 16.55 FEET; THENCE S.83°56’01"W. ALONG SAID BANK LINE, A DISTANCE OF 12.88 FEET; THENCE S.82° 13’20"W. ALONG SAID BANK LINE, A DISTANCE OF 16.26 FEET; THENCE S.86°54156"W. ALONG SAID BANK LINE, A DISTANCE OF 38.51 FEET; THENCE S.81°19’51 "W. ALONG SAID BANK LINE, A DISTANCE OF 56.23 FEET; THENCE S.78°20’25"W. ALONG SAID BANK LINE, A DISTANCE OF 96.67 FEET; THENCE S.77°28’58"W. ALONG SAID BANK LINE, A DISTANCE OF 7.80 FEET; THENCE S.65°59’35"W. ALONG SAID BANK LINE, A DISTANCE OF 29.22 FEET; THENCE S.73°48’18"W. ALONG SAID BANK LINE, A DISTANCE OF 99.41 FEET; THENCE S.64°36’44"W. ALONG SAID BANK LINE, A DISTANCE OF 26.36 FEET; THENCE S.82°04’51"W. ALONG SAID BANK LINE, A DISTANCE OF 37.59 FEET; THENCE S.79°11’42"W. ALONG SAID BANK LINE, A DISTANCE OF 24.10 FEET; THENCE S.67°19’56"W. ALONG SAID BANK LINE, A DISTANCE OF 36.60 FEET; THENCE S.57°29’04"W. ALONG SAID BANK LINE, A DISTANCE OF 67.73 FEET; THENCE S.73°11’42"W. ALONG SAID BANK LINE, A DISTANCE OF 12.84 FEET; THENCE S.85°50’50"W.ALONG SAID BANK LINE, A DISTANCE OF 60.97 FEET; THENCE S.82°03’49"W. ALONG SAID BANK LINE, A DISTANCE OF 43.23 FEET; THENCE S.74°06’05"W. ALONG SAID BANK LINE, A DISTANCE OF 65.82 FEET; THENCE S.69°58’55"W. ALONG SAID BANK LINE, A DISTANCE OF 56.83 FEET; THENCE S.74°57’43"W. ALONG SAID BANK LINE, A DISTANCE OF 83.02 FEET; THENCE S.70°20’31 "W. ALONG SAID BANK LINE, A DISTANCE OF 124.35 FEET; THENCE S.68°05’01"W. ALONG SAID BANK LINE, A DISTANCE OF 84.42 FEET; THENCE S.66°49’24"W.ALONG SAID BANK LINE, A DISTANCE OF 78.63 FEET; THENCE S.63°59’05"W. ALONG SAID BANK LINE, A


DISTANCE OF 66.34 FEET; THENCE S.62°09’08”W. ALONG SAID BANK LINE, A DISTANCE OF 87.15 FEET; THENCE S.53°30’53”W. ALONG SAID BANK LINE, A DISTANCE OF 16.00 FEET; THENCE S.53°32’22”W. ALONG SAID BANK LINE, A DISTANCE OF 49.40 FEET; THENCE S.56°34’01”W. ALONG SAID BANK LINE, A DISTANCE OF 39.73 FEET; THENCE S.60°13’05”W. ALONG SAID BANK LINE, A DISTANCE OF 50.12 FEET; THENCE S.59°36’42”W.ALONG SAID BANK LINE, A DISTANCE OF 53.89 FEET; THENCE S.53°21’39”W. ALONG SAID BANK LINE, A DISTANCE OF 48.07 FEET; THENCE S.52°33’03”W. ALONG SAID BANK LINE, A DISTANCE OF 51.08 FEET; THENCE S.54°23’00”W. ALONG SAID BANK LINE, A DISTANCE OF 2.82 FEET; THENCE S.72°46’01”W. ALONG SAID BANK LINE, A DISTANCE OF 8.65 FEET; THENCE S.69°52’59”W. ALONG SAID BANK LINE, A DISTANCE OF 10.25 FEET; THENCE S.55°33’28”W. ALONG SAID BANK LINE, A DISTANCE OF 89.25 FEET; THENCE S.46°08’21”W. ALONG SAID BANK LINE, A DISTANCE OF 23.61 FEET; THENCE S.48°47’06”W. ALONG SAID BANK LINE, A DISTANCE OF 33.34 FEET; THENCE S.44°49’08”W. ALONG SAID BANK LINE, A DISTANCE OF 28.62 FEET; THENCE S.51°28’43”W. ALONG SAID BANK LINE, A DISTANCE OF 9.51 FEET; THENCE S.48°39’39”W. ALONG SAID BANK LINE, A DISTANCE OF 9.06 FEET; THENCE S.37°40’35”W. ALONG SAID BANK LINE, A DISTANCE OF 15.69 FEET; THENCE S.40°02’01”W. ALONG SAID BANK LINE, A DISTANCE OF 51.20 FEET; THENCE S.49°11‘35”W.ALONG SAID BANK LINE, A DISTANCE OF 8.67 FEET; THENCE S.35°28’18”W., A DISTANCE OF 91.58 FEET TO THE INTERSECTION OF SAID BANK LINE AND THE SOUTH LINE OF SECTION 33, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE INCH DIAMETER IRON PIPE, OFFSET 55.62’ N.89°08’27”W. OF TRUE POSITION; THENCE N.89°08’27”W. ALONG THE SOUTH LINE OF SECTION 33, A DISTANCE OF 664.49 FEET TO A POINT BEING MARKED BY A FOUND FOUR INCH DIAMETER TRANSITE PIPE; THENCE N.89°08’27”W. ALONG THE SOUTH LINE OF SECTION 33, A DISTANCE OF 21 8.23 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.89°08’27”W., A DISTANCE OF 796.38FEET TO THE INTERSECTION OF THE SOUTH LINE OF SECTION 33 AND THE LEFT DESCENDING BANK LINE OF THE CALCASIEU RIVER SHIP CHANNEL, SAID POINT BEING MARKED BY A FOUND ONE INCH DIAMETER IRON PIPE, OFFSET 100.93’ S.89°08’27”E. OF TRUE POSITION; THENCE N.12°01‘1 3”W. ALONG SAID BANK LINE, A DISTANCE OF 9.03 FEET; THENCE N.13°12’06”W. ALONG SAID BANK LINE, A DISTANCE OF 13.72 FEET; THENCE N.11°50’30”W. ALONG SAID BANK LINE, A DISTANCE OF 25.86 FEET; THENCE N.09°10’45”W. ALONG SAID BANK LINE, A DISTANCE OF 25.22 FEET; THENCE N.09°48’01”W. ALONG SAID BANK LINE, A DISTANCE OF 45.81 FEET; THENCE N.12°14’30”W. ALONG SAID BANK LINE, A DISTANCE OF 17.21 FEET; THENCE N.38°36’07”W. ALONG SAID BANK LINE, A DISTANCE OF 6.59 FEET; THENCE N.15°00’00”W. ALONG SAID BANK LINE, A DISTANCE OF 14.00 FEET; THENCE N.21°20’05”W. ALONG SAID BANK LINE, A DISTANCE OF 8.36 FEET; THENCE N.32°06’14”W. ALONG SAID BANK LINE, A DISTANCE OF 9.53 FEET; THENCE N.11.28’49”W. ALONG SAID BANK LINE, A DISTANCE OF 27.33 FEET; THENCE N.12°32’02”W. ALONG SAID BANK LINE, A DISTANCE OF 35.26 FEET; THENCE N.21°30’55”W. ALONG SAID BANK LINE, A DISTANCE OF 31.35 FEET; THENCE N.05°02’51”E. ALONG SAID BANK LINE, A DISTANCE OF 7.40 FEET; THENCE N.21°15’49”E. ALONG SAID BANK LINE, A DISTANCE OF 6.85 FEET; THENCE


N.26°50’07”E. ALONG SAID BANK LINE, A DISTANCE OF 5.38 FEET; THENCE N.26°55’53”E. ALONG SAID BANK LINE, A DISTANCE OF 3.42 FEET; THENCE N.19°59’54”E. ALONG SAID BANK LINE, A DISTANCE OF 3.0 1 FEET; THENCE N.11°37’07”E. ALONG SAID BANK LINE, A DISTANCE OF 14.94 FEET; THENCE N.09°47’35”E. ALONG SAID BANK LINE, A DISTANCE OF 16.21 FEET; THENCE N.07°46’15”W. ALONG SAID BANK LINE, A DISTANCE OF 5.00 FEET; THENCE N.15°39’24”W. ALONG SAID BANK LINE, A DISTANCE OF 2.95 FEET; THENCE N. 11°27’36”W. ALONG SAID BANK LINE, A DISTANCE OF 4.58 FEET; THENCE N.07°33’26”W. ALONG SAID BANK LINE, A DISTANCE OF 4.76 FEET; THENCE N.03°56’14”W. ALONG SAID BANK LINE, A DISTANCE OF 10.31 FEET; THENCE N.04°14’27”W. ALONG SAID BANK LINE, A DISTANCE OF 2.07 FEET; THENCE N.04°11’21”E. ALONG SAID BANK LINE, A DISTANCE OF 6.31 FEET; THENCE N.04°35’12”E. ALONG SAID BANK LINE, A DISTANCE OF 6.13 FEET; THENCE N.02°16’26”W. ALONG SAID BANK LINE, A DISTANCE OF 18.68 FEET; THENCE N.04°52’31”W. ALONG SAID BANK LINE, A DISTANCE OF 5.68 FEET; THENCE N.09°59’25”W. ALONG SAID BANK LINE, A DISTANCE OF 3.83 FEET; THENCE N.16°15’59”W. ALONG SAID BANK LINE, A DISTANCE OF 3.16 FEET; THENCE N.19°15’41”W. ALONG SAID BANK LINE, A DISTANCE OF 7.64 FEET; THENCE N.23°04’18”W. ALONG SAID BANK LINE, A DISTANCE OF 9.24 FEET; THENCE N.39°29’46”W. ALONG SAID BANK LINE, A DISTANCE OF 5.76 FEET; THENCE N.38°53’26”W. ALONG SAID BANK LINE, A DISTANCE OF 5.79 FEET; THENCE N.19°03’54”W. ALONG SAID BANK LINE, A DISTANCE OF 1.95 FEET; THENCE N.03°57’38”W. ALONG SAID BANK LINE, A DISTANCE OF 4.14 FEET; THENCE N.01°20’30”E. ALONG SAID BANK LINE, A DISTANCE OF 14.00 FEET; THENCE N.01°50’10”W. ALONG SAID BANK LINE, A DISTANCE OF 14.28 FEET; THENCE N.01°54’32”W. ALONG SAID BANK LINE, A DISTANCE OF 24.08 FEET; THENCE N.02°07’32”W. ALONG SAID BANK LINE, A DISTANCE OF 36.97 FEET; THENCE N.05°40’18”E. ALONG SAID BANK LINE, A DISTANCE OF 54.97 FEET; THENCE N.08°00’27”E. ALONG SAID BANK LINE, A DISTANCE OF 69.22 FEET; THENCE N.09°07’24”E. ALONG SAID BANK LINE, A DISTANCE OF 60.95 FEET; THENCE N.02°49’40”E. ALONG SAID BANK LINE, A DISTANCE OF 54.31 FEET; THENCE N.00°32’22”E. ALONG SAID BANK LINE, A DISTANCE OF 66.62 FEET; THENCE N.07°32’24”W. ALONG SAID BANK LINE, A DISTANCE OF 47.54 FEET; THENCE N.01°17’48”W. ALONG SAID BANK LINE, A DISTANCE OF 51.02 FEET; THENCE N.01°09’14”W. ALONG SAID BANK LINE, A DISTANCE OF 31.16 FEET; THENCE N.29°38’28”W. ALONG SAID BANK LINE, A DISTANCE OF 16.32; THENCE N.35°49’39”W. ALONG SAID BANK LINE, A DISTANCE OF 16.82 FEET; THENCE N.05°17’18”W. ALONG SAID BANK LINE, A DISTANCE OF 39.52 FEET; THENCE N.04°29’49”W. ALONG SAID BANK LINE, A DISTANCE OF 64.81 FEET; THENCE N.03°46’33”W. ALONG SAID BANK LINE, A DISTANCE OF 51.38 FEET; THENCE N.01°00’14”E. ALONG SAID BANK LINE, A DISTANCE OF 13.95 FEET; THENCE N.07°53’30”E. ALONG SAID BANK LINE, A DISTANCE OF 8.71 FEET; THENCE N.13°47’09”E. ALONG SAID BANK LINE, A DISTANCE OF 44.48 FEET; THENCE N.00°49’09”W. ALONG SAID BANK LINE, A DISTANCE OF 4.37 FEET; THENCE N.05°52’29”W. ALONG SAID BANK LINE, A DISTANCE OF 3.67 FEET; THENCE N.09°05’07”W. ALONG SAID BANK LINE, A DISTANCE OF 38.47 FEET; THENCE N.09°05’07”W. ALONG SAID BANK LINE, A DISTANCE OF 1 6.8 1 FEET; THENCE N.17°06’44”W. ALONG SAID BANK LINE, A DISTANCE OF 38.94 FEET; THENCE N.07°01’37”W. ALONG SAID BANK LINE, A


DISTANCE OF 65.92 FEET; THENCE N.05°42’26”W. ALONG SAID BANK LINE, A DISTANCE OF 77.66 FEET; THENCE N.00°51’16”E. ALONG SAID BANK LINE, A DISTANCE OF 36.32 FEET; THENCE N.03°05’03”E. ALONG SAID BANK LINE, A DISTANCE OF 29.34 FEET; THENCE N.00°22’33”W. ALONG SAID BANK LINE, A DISTANCE OF 38.30 FEET; THENCE N.05°40’07”W. ALONG SAID BANK LINE, A DISTANCE OF 28.04 FEET; THENCE N.05°19’56”W. ALONG SAID BANK LINE, A DISTANCE OF 35.60 FEET; THENCE N.01°58’25”W. ALONG SAID BANK LINE, A DISTANCE OF 22.76 FEET; THENCE N.09°1 0’22”E. ALONG SAID BANK LINE, A DISTANCE OF 66.29 FEET; THENCE N.09°55’28”E. ALONG SAID BANK LINE, A DISTANCE OF 59.88 FEET; THENCE N.08°03’39”E. ALONG SAID BANK LINE, A DISTANCE OF 28.85 FEET; THENCE N.04°07’49”E. ALONG SAID BANK LINE, A DISTANCE OF 20.6 1 FEET; THENCE N.0 l 054’33”E. ALONG SAID BANK LINE, A DISTANCE OF 34.26 FEET; THENCE N.13°46’26”E. ALONG SAID BANK LINE, A DISTANCE OF 39. 13 FEET; THENCE N.45°37’49”E., A DISTANCE OF 11.87 FEET TO THE INTERSECTION OF SAID BANK LINE AND THE NORTH LINE OF SECTION 34, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 100.19’ S.88°59’12”E. OF TRUE POSITION; THENCE S.88°59’12”E. ALONG THE NORTH LINE OF SECTION 34, A DISTANCE OF 1,948.66 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.88°59’12”E. ALONG THE NORTH LINE OF SECTION 34, A DISTANCE OF 265.06 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.88°59’12”E., A DISTANCE OF 1,638.73 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 5,935,210.92 SQUARE FEET OR 136.2537 ACRES, MORE OR LESS, IS SITUATED IN IRREGULAR SECTIONS 33 & 34, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL ‘‘P”


LOGO


LOGO


LOGO


LOGO


LOGO


EXHIBIT 2

SITE SURVEY

[Omitted]


EXHIBIT 3

TENANT’S RESOLUTION

[Omitted]


EXHIBIT 4

LANDLORD’S RESOLUTION

[Omitted]


EXHIBIT 5

FORM OF NON-DISTURBANCE AGREEMENT

[Omitted]

Exhibit 10.59

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

 

STATE OF LOUISIANA   
PARISH OF CAMERON    Execution Version

GROUND LEASE AGREEMENT

(162 Acres)

This GROUND LEASE AGREEMENT (this “Ground Lease”) is executed and effective as of October 12, 2023 (the “Ground Lease Commencement Date”), by and between Venture Global CP2 LNG, LLC, a Delaware limited liability company (the “Tenant”), and Miller Estate Leasing Company, LLC, a Louisiana limited liability company (the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Cameron Parish, Louisiana, which comprises approximately one hundred sixty-two (162) acres; and

WHEREAS, the Tenant wishes to lease land owned by the Landlord for the construction, development and operation of a natural gas liquefaction facility and liquefied natural gas (“LNG”) export terminal (the “Facilities”) and other uses permitted by this Ground Lease; and

WHEREAS, in accordance with the above, the Tenant has executed this Ground Lease and offers fair value to the Landlord as cause and consideration for this Ground Lease.

NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this Ground Lease, and the Parties herein covenant and agree as follows:

1. Definitions and Interpretation.

As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

Adjustment Period” has the meaning set forth in Section 4.1 (c).

Affiliate” means any Person controlled by, controlling or under common control with the Landlord or the Tenant, as applicable. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of thirty percent (30%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.

Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Site.

 

1


Execution Version

 

Bankruptcy Proceeding” has the meaning set forth in Section 23.10.

Bona Fide Offer” has the meaning set forth in Section 14.3.

Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in the State of New York are authorized or required by law to close.

Consumer Price Index” has the meaning set forth in Section 4.2.

Corps” has the meaning set forth in Section 8.3(a).

Corrective Measures” has the meaning set forth in Section 9.4(b).

CPI Adjustment” has the meaning set forth in Section 4.1.

CPI Disagreement Notice” has the meaning set forth in Section 4.2.

CPI Notice” has the meaning set forth in Section 4.2.

CPI Percentage Increase” has the meaning set forth in Section 4.2.

Environmental Evaluation Procedure” has the meaning set forth in Section 9.4(b).

Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Laws or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Laws relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

Environmental Study” has the meaning set forth in Section 9.4(b).

Event of Default” has the meaning set forth in Section 15.1.

Extended Term” has the meaning set forth in Section 3.2(a).

Facilities” has the meaning set forth in the Recitals hereof.

Facility Contractors” means, collectively, the Persons engaged by the Tenant to construct the Facilities and/or develop the Facilities, the Site and/or the Improvements.

 

2


Execution Version

 

Facility Contracts” means, collectively, the contracts entered into by the Tenant in connection with the design, construction, equipment procurement, operation and maintenance of the Facilities, the Site and/or the Improvements.

Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Facilities, the Improvements, the Site, or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders. In no event shall Financing Parties include any Affiliate of Tenant or its assigns.

Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, droughts, floods, washouts, explosions, breakage or accident or necessity of repairs to machinery or equipment or lines of pipe; (ii) weather related events affecting an entire geographic region; (iii) acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, terrorism, discovery of burial grounds or human remains or legally protected artifacts, insurrections or wars; (iv) the failure or interruption of performance by the Tenant’s engineering, procurement and construction contractor or any subcontractors of such contractor to the extent caused by an event of Force Majeure under this Ground Lease; (v) the failure or interruption of performance by the Tenant’s suppliers by reason of such supplier’s valid declaration of an event that would constitute an event of force majeure under the Tenant’s contract with such supplier; and (vi) governmental actions such as necessity for compliance with any court order, law, statute, ordinance, regulation, or policy having the effect of law promulgated by a Governmental Authority having jurisdiction, or that restrict the Tenant’s ability to reasonably construct and/or operate the Facilities or the Improvements or any delay in issuance or effectiveness of any Governmental Approval that has been properly applied for by the Tenant that is required to construct and/or operate the Facilities or the Improvements. Force Majeure shall not apply to performance of financial obligations hereunder and shall not include Tenant’s financial inability to construct and/or operate the Facilities or the Improvements.

Governmental Approval” means any authorization, waiver, consent, approval, license, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority.

Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

Ground Lease” has the meaning set forth in the Preamble hereof.

 

3


Execution Version

 

Ground Lease Commencement Date” has the meaning set forth in the Preamble hereof.

Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

Hazardous Substances Law” means any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Laws or similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent it relates to the handling of and exposure to hazardous or toxic materials or similar substances.

Holding Over Rent” has the meaning set forth in Section 7.1.

Improvements” means any and all improvements made by Tenant, in its sole discretion, to the Site, including but not limited to, improvements relating to the loading, unloading, handling, treatment, processing, producing, transporting, distributing, selling, metering and/or storing of (i) natural gas, natural gas liquids, and other natural gas products, derivatives and by-products and (ii) other petroleum and hydrocarbon liquids, gases, products, derivatives and by-products, including but not limited to (A) the importation, regasification, production, exportation, liquefaction, refinement, enhancement, other treatment and transportation (including by ship, pipeline, truck or rail) of LNG, and LNG by-products and additives and (B) the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion,

 

4


Execution Version

 

optimization, alteration and/or removal of any improvements, component parts and other constructions, fixtures, facilities, equipment and/or appurtenances (including natural gas pipelines, natural gas liquids extraction, processing and delivery facilities, acid gas removal units, natural gas liquefaction trains, LNG regasification facilities, and other treatment facilities, cryogenic pipelines, LNG storage tanks, petroleum and other hydrocarbon liquids storage facilities, nitrogen storage and processing facilities, power generation and transmission infrastructure, marine, rail and trucking receipt, delivery and servicing facilities (including piers, marine terminals, bulkheads, wharfs, docks, inlets, wetslips, moonpools, moorings, jetties, and loading and unloading equipment), and other utilities and facilities (including berms, open space, security fencing, control rooms, offices, warehouses, parking and yards), in each case, necessary, ancillary or desirable to the Tenant in connection with the foregoing.

Initial Term” has the meaning set forth in Section 3.1.

Landlord” has the meaning set forth in the Preamble hereof.

Landlord Estoppel” has the meaning set forth in Section 23.11(a).

Landlord Indemnitee” has the meaning set forth in Section 9.1.

Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, affiliates, invitees, lessees (other than Tenant), agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Site, Landlord’s adjacent property and/or Landlord’s Improvements.

Landlord’s Event of Default” has the meaning set forth in Section 16.1.

Landlord’s Improvements” has the meaning set forth in Section 6.1.

Lease Year” means a period of twelve (12) consecutive full calendar months. The first Lease Year shall begin on the Ground Lease Commencement Date. Each succeeding Lease Year shall commence upon the anniversary of the first day of the previous Lease Year.

Leasehold Lenders” has the meaning set forth in Section 23.1.

Leasehold Loan” has the meaning set forth in Section 23.1.

Leasehold Mortgage” has the meaning set forth in Section 23.1.

Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

LNG” has the meaning set forth in the Recitals hereof.

 

5


Execution Version

 

Minerals” has the meaning set forth in Section 8.3(b).

New Lease” has the meaning set forth in Section 23.9(a).

Non-Disturbance Agreement” has the meaning set forth in Section 23.11(c).

Option Agreement” means the Real Estate Lease Option Agreement between the Landlord and the Tenant (as successor in interest to Cameron Land Ventures, LLC), dated as of November 10, 2020.

Party’’ or “Parties” has the meaning set forth in the Preamble hereof.

Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

Property Taxes” means all real (immovable) and personal (movable) property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

Removal Period” means the period of time that is required by the Tenant to remove any and all of Tenant’s Property, including the Facilities and/or Improvements, from the Site in accordance with Section 7.1.

Rent” has the meaning set forth in Section 4.1.

Site” means the real (immovable) property of approximately one hundred sixty-two (162) acres described in the legal description set forth in Exhibit 1, and illustrated by the Survey Map attached as Exhibit 2, upon which the Facilities and any Improvements will be located and which real (immovable) property is owned by the Landlord.

Surface Waiver” has the meaning set forth in Section 8.3(b).

Survey Map” means the ALTA survey of the Site, dated November 27, 2019, by Lonnie G. Harper & Associates, Inc., attached as Exhibit 2.

Tenant” has the meaning set forth in the Preamble hereof.

Tenant Estoppel” has the meaning set forth in Section 23.11(b).

Tenant Indemnitee” has the meaning set forth in Section 9.3.

Tenant’s Activities” have the meaning set forth in Section 9.4(a).

 

6


Execution Version

 

Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Site by or on behalf of the Tenant, including the Facilities and any Improvements.

Third Appraiser” has the meaning set forth in Section 14.5.

1.2 Interpretation. Unless the context otherwise requires:

(a) Words singular and plural in number will be deemed to include the other and pronouns having a masculine or feminine gender will be deemed to include the other;

(b) Any reference to this Ground Lease or any other contract or agreement in respect of the Site means such agreement and all schedules, exhibits and attachments thereto as may be amended, supplemented or otherwise modified and in effect from time to time, and shall include a reference to any document which amends, modifies or supplements it, or is entered into, made or given pursuant to or in accordance with its terms;

(c) The terms “hereof,” “herein,” “hereby,” “hereto” and similar words refer to this entire Agreement and not any particular Section, subsection or other subdivision of, or Exhibit, appendix or schedule to, this Ground Lease;

(d) The terms “include” and “including” shall be construed as being at all times followed by the words “without limitation” or “but not limited to” unless the context specifically indicates otherwise;

(e) References to “Article,” “Section” or “Exhibit” are to this Ground Lease unless specified otherwise;

(f) References to any law, statute, rule, regulation, notification or statutory provision (including Applicable Laws) shall be construed as a reference to the same as it may have been, or may from time to time be, amended, modified or re-enacted;

(g) References to any Person shall be construed as a reference to such Person’s successors, heirs and permitted assigns; and

(h) The word “or” will have the inclusive meaning represented by the phrase “and/or”.

2. Ground Lease Premises.

2.1 Date. The date of this Ground Lease is the Ground Lease Commencement Date.

2.2 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of the rents and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does lease to the Tenant and the Tenant hereby leases from the Landlord, the Site and Landlord’s Improvements.

 

7


Execution Version

 

2.3 Servitudes. In addition, the Landlord shall without cost to the Tenant, grant from time to time to the Tenant and others designated by the Tenant any reasonably necessary easements, servitudes, and rights of way for access and electricity, communications, gas, water, sewer and other utility lines, products and materials from and to the Site over land and waterways sufficient and reasonably necessary to permit the Tenant to accomplish its purposes in connection with the Improvements or the Facilities; provided, however, that such servitudes, easements and rights of way are in locations that are typical for the type and use and are in areas reasonable acceptable to Landlord in its reasonable discretion and automatically terminate at the termination or expiration of this Ground Lease.

3. Term

3.1 Initial Term. The initial term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on the thirtieth (30th) anniversary of the last day of the month immediately preceding the Ground Lease Commencement Date (the “Initial Term”).

3.2 Extensions.

(a) In consideration of and conditioned upon there being no uncured Event of Default on the part of the Tenant at the time an option is exercised, the Landlord hereby grants unto the Tenant the option to lease the Site for four (4) additional ten (10) year terms. If the extension option is exercised in accordance with Section 3.2(b), the first of said additional terms shall commence upon the expiration of the Initial Term and extend for a period of ten (10) years and each of said additional terms shall commence upon the expiration of the then-current additional term and extend for a period of ten (10) years; provided, the Tenant has timely exercised each option to renew and provided further that at the time of the exercise of the option to renew and at the commencement date of each Extended Term (as hereinafter defined) there shall not exist any uncured Event of Default. Each of such additional terms is referred to herein as an “Extended Term” and, collectively, the Initial Term and any Extended Terms are referred to herein as the “Term”.

(b) The option to extend this Ground Lease of the Site as set forth in Section 3.2(a) must be exercised in each case, if at all, by written notice from the Tenant to the Landlord on or before the date that is three (3) months prior to the expiration of the Initial Term or the then-current Extended Term, as applicable. The failure of the Tenant to timely exercise the first Extended Term or any subsequent Extended Term shall automatically terminate the right of the Tenant to exercise its option to lease the Site in any subsequent Extended Term.

(c) All the terms and conditions of this Ground Lease shall be applicable to any Extended Term and the Rent payable by the Tenant for any Extended Term shall be in accordance with the provisions set forth in Article 4.

 

8


Execution Version

 

4. Rent.

4.1 Rent. Commencing upon the Ground Lease Commencement Date, the initial rent for the Site (“Rent”) shall be [***] per annum, payable in equal installments of [***] per month, adjusted upward every three (3) years thereafter during the Initial Term and during any Extended Term by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment for any Adjustment Period (as defined below) of greater than [***]. The period of time from the Ground Lease Commencement Date through the date three years thereafter, and each three (3) year period thereafter shall be defined herein as an “Adjustment Period.” Any upward adjustment based on a CPI Percentage Increase (as defined below) to any payment under this Ground Lease shall hereinafter be referred to as a “CPI Adjustment.” Such Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month, provided however, that: (a) the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; and (b) the first payment of Rent due upon the commencement of any new Adjustment Period will be owed and paid one month after the commencement of that Adjustment Period, in order to permit the Tenant to calculate and include the CPI Adjustment as provided in Section 4.2.

4.2 CPI Adjustment. If CPI Percentage Increase (as defined below) is more than [***] for the relevant Adjustment Period, then the Rent payable during that Adjustment Period shall be adjusted upward by a percentage equal to the CPI Percentage Increase (as defined below) applicable to such Adjustment Period, but not to exceed an adjustment during any Adjustment Period of greater than [***]. The term “Consumer Price Index” shall mean the unadjusted Consumer Price Index for All Urban Workers, U.S. City Average, All Items, 1982-84=100, calculated and published by the United States Department of Labor, Bureau of Labor Statistics. The “CPI Percentage Increase” shall mean, with respect to any Adjustment Period, [***]. For the avoidance of doubt, no CPI Adjustment shall be made to any payment due under this Ground Lease for any Adjustment Period if the result of such CPI Adjustment would be to (a) reduce the amount of such payment to an amount that is less than the amount of such payment due for the immediately preceding Adjustment Period or (b) to raise the amount of such payment to an amount that is greater than [***]. For illustrative purposes only, [***].

 

9


Execution Version

 

The CPI Percentage Increase for any Adjustment Period shall be calculated by the Tenant, and the Tenant shall deliver written notice to the Landlord describing such calculation in reasonable detail (a “CPI Notice”) no later than thirty (30) days after the commencement of any Adjustment Period. Such notice shall also inform the LANDLORD that this Section 4.2 provides that if the LANDLORD does not deliver a CPI Disagreement notice within 30 days it shall forfeit its right to contest it. If the Landlord disagrees with the Tenant’s calculation of the CPI Percentage Increase, then the Landlord shall deliver to the Tenant written notice, describing the basis for such disagreement in reasonable detail (a “CPI Disagreement Notice”), not later than thirty (30) days after delivery of the CPI Notice. If the Landlord fails to deliver a CPI Disagreement Notice within thirty (30) days after delivery of any CPI Notice, then the Landlord shall be conclusively deemed to have agreed with the calculation of the CPI Percentage Increase set forth in such CPI Notice.

4.3 Due Date. Except as otherwise provided in this Ground Lease, all Rent payments shall be due and payable in advance on the 1st calendar day of each month and shall be subject to a late fee if not paid by the 15th calendar day of each month during the entire term of this Ground Lease; provided, however, that the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month.

4.4 Place of Payment. Except as otherwise provided herein, Rent shall be payable by check or wire transfer at the following address or via wire instructions provided by the Landlord to the Tenant in writing, or to such other place as the Landlord may specify, as hereinafter provided, from time to time: [***].

5. Triple Net Lease; Taxes and Utility Expenses.

5. I Triple Net Lease. This Ground Lease is a triple net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs, if any, of every kind and nature whatsoever relating to the Site except as expressly otherwise provided in this Ground Lease.

5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and Governmental Approval fees applicable to the Site during the term of this Ground Lease.

(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on or related to the Site and Improvements, including the underlying real property comprising the Site during the term of this Ground Lease (prorated on the basis of a 365-day year to account for any fractional portion of a fiscal tax year included in at the commencement or expiration of the Term). The Landlord shall promptly provide all Property Tax bills when they become available. Upon the latter of (i) one (1) month after receipt of such Property Tax bill from the Landlord or (ii) the due date of any such Property Taxes, the Tenant shall provide the Landlord with reasonable written evidence from the Cameron Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

 

10


Execution Version

 

(c) The Landlord shall provide written notice to the Tenant of its receipt of any oral or written notice of any audit, examination, claim or assessment relating to Property Taxes on or related to the Improvements within ten (10) Business Days following receipt of such notice. The Tenant may, or if, required by Applicable Law, the Landlord shall at the Tenant’s election and at Tenant’s expense (including attorney fees and costs), and in compliance with the Tenant’s direction, initiate a claim and commence proceedings with the appropriate Governmental Authority to contest, resolve, appeal, defend and settle any such audit, examination, claim or assessment, as applicable, relating to Property Taxes, and in, any event, the Landlord shall fully cooperate with the Tenant with respect to any such claim or proceeding and Tenant shall pay all reasonable costs and expenses incurred by Landlord in doing so. The Landlord and the Tenant shall otherwise reasonably cooperate to minimize assessed value of the Improvements and underlying real property, at Tenant’s expense, and coordinate to properly and timely remit Property Taxes assessed and owed, including through coordination with the Cameron Parish Tax Collector’s Office, the Cameron Parish Tax Assessor’s Office and any other relevant Governmental Authorities.

5.3 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost, electricity, telephone, water, sewerage, gas, and other utility services to the Site; provided, however, the Landlord shall cooperate, and to the extent reasonably needed, facilitate the contracting of any easements, servitudes and/or rights of way, and grant easements, servitudes and rights of way in accordance with Section 2.3, as required by the Tenant for such utility connections and/or services.

6. Tenant and Landlord Improvements.

6.1 Landlord’s Improvements. “Landlord’s Improvements” are any and all improvements to the immovable property of the Site and any and all movable property in existence on the Site at the time of the Ground Lease Commencement Date. There are no Landlord’s Improvements.

6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install on the Site, any Improvements during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. The Tenant shall be permitted to make any changes, improvements or alterations to the Site, including, without limitation, the Facilities and any Improvements to the Site, during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws.

 

11


Execution Version

 

6.3 Governmental Approvals. The Landlord will cooperate and assist (and never oppose) the Tenant in obtaining any and all Governmental Approvals deemed necessary by the Tenant for the Facilities and all other Improvements to the Site, including with respect to Governmental Approvals from the Federal Energy Regulatory Commission and the Department of Energy. The Landlord will hereafter continue to be obligated to execute appropriate documentation to waive its right to require wetlands mitigation to be completed on the Site or other real (immovable) property owned by the Landlord, in such form as necessary to allow the Tenant to complete such wetlands mitigation at locations other than other real (immovable) property owned by the Landlord. To the extent permitted by Applicable Laws, Tenant shall secure on Landlord’s behalf, as owner of the Site, but at Tenant’s expense, any Governmental Approvals required by Governmental Authorities in relation thereto during the Initial Term and/or any Extended Term.

6.4 Tenant’s Property. Tenant’s Property shall at all times be and remain the sole property of the Tenant except as provided in Section 7.

6.5 Maintenance of Improvements.

(a) Tenant’s Obligation to Maintain. During the Initial Term or any Extended Term, as applicable, the Tenant will keep in reasonably good state of repair the Site, the Facilities, the Improvements, open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Site by the Tenant, and the Tenant will, in its sole discretion and cost, repair such property as often as may be necessary in order to keep the Facilities and the Improvements in reasonably good repair and condition, except as set forth in Section 6.5(b).

(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease, the Landlord has no obligation to maintain the Site, Improvements and/or Landlord’s Improvements (if any) during the Initial Term and/or any Extended Term. The Landlord further agrees that there will be no Landlord improvements on the Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

7. Tenant’s Surrender of Site.

7.1 Surrender at End of Ground Lease. Subject to and subordinate to Section 23 and the rights of any Leasehold Lender under any Leasehold Mortgage, the Tenant shall and will on the last day of the Initial Term, or if extended, on the last day of the Extended Term hereof, surrender and deliver the Site to the Landlord, in good order and condition (except as provided in Section 13), excepting normal wear and tear. Any holding over by Tenant shall not operate, except by written agreement of Tenant and Landlord, to extend or renew this Lease for an additional Extension Term, but in such case, Landlord may consider such occupancy to be from month to month with rent increased to one hundred twenty percent (120%) of the Rent due for the immediately preceding month (“Holding Over Rent”). Prior to the expiration of the Term of this Ground Lease, or within ninety (90) days following an early termination of this Ground Lease, the Tenant shall in good faith complete (i) any removal of the Facilities and any and all Improvements and (ii) restoration, if any, of the Site to its condition prior to construction of the Facilities and/or

 

12


Execution Version

 

Improvements. The Tenant shall have all access rights to the Site that are necessary to remove any and all of the Tenant’s Property, including the Facilities and/or Improvements, and shall pay Holding Over Rent during such time as Tenant retains access to the Site to do so. The Tenant shall also comply as required by any federal regulations of the Federal Energy Regulatory Commission or any other federal authority with respect to the Facilities and the Site.

7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date the Tenant shall assume full dominion, control and responsibility for the Site, except to the extent specifically provided herein, to the extent provided under LSA – R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real (immovable) or personal (movable) property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its officers, representatives, agents, or employees or the Landlord’s material misrepresentations or its breach of or default under this Ground Lease.

7.3 Holding Over. If the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, including the payment of the Holding Over Rent, and shall not constitute a renewal or extension of the term of this Ground Lease.

7.4. Acknowledgement of Termination or Expiration. On the last day of the Initial Term, or if extended, on the last day of the Extended Term, or if the Lease should expire or be terminated for any reason, Tenant shall within thirty (30) days thereof provide Landlord with an acknowledgement of such termination executed by an authorized representative in a form suitable for recordation in the conveyance records of Cameron Parish.

8. Use.

8.1 Permitted Uses; Compliance with Laws: Permits. The Tenant may use the Site for any and all uses desired by the Tenant in compliance with all Applicable Laws. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the construction, operation, and maintenance of the Facilities, the Improvements and/or for the Tenant’s use or activities on the Site. The Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Facilities, the Improvements, and the security of the Site, including the timely filing, implementation, and enforcement of any security plan required by Applicable Laws. Any fine or penalty imposed by any Governmental Authority to the extent caused by the failure of the Tenant to comply with this provision, including any fine or penalty imposed upon the Landlord as owner of the Site as to the extent caused by the failure of the Tenant to comply with this provision, shall be the sole responsibility of the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall defend, indemnify and hold harmless the Landlord from the payment of any such fine or penalty, and the Tenant shall, to the extent permitted under Applicable Laws, pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord.

 

13


Execution Version

 

8.2 Dirt Moving Activities; Permits; Timber.

(a) The Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Site, to the Site, and from portions of the Site to other portions of the Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Site and may do so with Landlord’s permission, which shall not be unreasonably withheld. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Site, including without limitation, for any Improvements, reclamation of lands, erosion control, attainment of spoil, easements/servitudes and/or rights of way; provided, that all costs associated with such efforts shall be the responsibility of the Tenant. Except only as provided in Section 8.2(b), the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Site, and all other rights as a tenant on and to the Site. Any activities of the Landlord shall not adversely affect the Site or the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any material way. Nothing herein is intended to preclude the Landlord, from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation or from exercising its rights if an Event of Default by Tenant exists. The Tenant may freely remove any timber which is standing or lying on the Site as the Tenant deems reasonably necessary for the Tenant’s intended use of the Site except as otherwise expressly provided. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights below the surface of the Site. At the termination or expiration of the Lease, Tenant shall return any portions of the Site that were dredged or from which muck, dirt, dredge spoil, fill or other materials were removed to its original condition, subject to normal wear and tear, as required by Section 7.1.

(b) To the extent the Landlord holds any rights to oil, gas, or other minerals (“Minerals”) in the Site, the Landlord waives any and all rights of the Landlord or its lessees or assignees to use the surface of the Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the term of this Ground Lease, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means consistent with the terms and conditions of this Section 8.3 (b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any way.

 

14


Execution Version

 

8.3 Oak Grove. Notwithstanding anything else to the contrary in this Lease, Tenant shall use reasonable efforts to design the Improvements and Facilities to be constructed on the Site, and to conduct Tenant’s use of the Site with, so as to preserve and maintain the portion of the Site designated as “Oak Grove” as set forth on Exhibit 2, attached hereto and made a part hereof as an undeveloped area of the Site. Nothing herein shall obligate Tenant to provide access to Oak Grove to the public or to diminish Tenant’s exclusive use of the Site under this Ground Lease.

8.4 Crossing. The Landlord shall assist the Tenant in the Tenant’s efforts to develop, at the Tenant’s cost, any roads and/or crossings or other Improvements across the Site and boundary lines of the Site to the adjacent land, including relocation of utilities, providing culverts for storm water drainage, and any other Improvements. The Tenant or others, excluding the Landlord, will pay the cost to relocate or modify the infrastructure for these roads and/or crossings and/or other Improvements. Utility servitudes and/or easements shall be in such locations as are acceptable to Landlord, in its reasonable discretion.

8.5 Access License Agreement. The Landlord hereby consents to the Tenant providing to the Tenant’s Affiliates non-exclusive access to the Site pursuant to one or more access license agreements with its applicable Affiliates; provided that the foregoing shall not serve to modify or limit any of the Landlord’s or the Tenant’s rights and obligations under, or the terms and conditions of, this Ground Lease. Upon Leasehold Lender’s or Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate consenting to such access and related access rights agreements.

9. Indemnification.

9.1 Tenant’s General Agreement to Indemnify. The Tenant releases the Landlord, its officers, members, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to defend, indemnify and hold harmless the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, witness fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Landlord Indemnitee arising out of (i) the use or occupancy of the Site by the Tenant, its officers, representatives, agents, contractors, licensees, Affiliates and employees, (ii) the construction or operation of the Facilities by the Tenant, its officers, representatives, agents, contractors, licensees, Affiliates and employees, (iii) any claim arising out of the use, occupancy, construction or operation of the Site by the Tenant, its officers, representatives, agents, contractors, licensees, Affiliates and employees, and (iv) activities on or about the Site by the Tenant, its officers, representatives, agents, contractors, licensees, Affiliates and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, operation, maintenance, or repair of the Site, the Facilities, or the Improvements, as well as the removal of the Facilities or the Improvements, by the Tenant, its officers, representatives, agents, contractors, licensees, Affiliates and employees; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the gross negligence or willful misconduct of any Landlord Indemnitee shall be excluded from this indemnity to the extent and only to the extent caused by the gross negligence or willful misconduct of any Landlord Indemnitee. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9.2 and 9.4 and not this Section 9.1.

 

15


Execution Version

 

9.2 Tenant’s Environmental Indemnification. For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with, and cause all of its officers, representatives, agents, contractors, licensees, Affiliates and employees to comply with, all Environmental Laws applicable to the Tenant, its officers, representatives, agents, contractors, licensees, Affiliates and employees, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Tenant agrees to indemnify and hold harmless the Landlord Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorney, accounting, consulting, engineering, and other fees and expenses), including but not limited to for wrongful death, which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth above in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Site or any violation of any Environmental Law with respect to the Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, use, occupancy, repair, removal and/or maintenance activities or facilities or the actions of Tenant’s officers, representatives, agents, contractors, licensees, Affiliates and employees, and not caused by the Landlord’s Activities or Landlord’s Improvements.

9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Site by the Landlord, its officers, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Site by the Landlord, its officers, representatives, agents, and employees, and (iii) activities on or about the Site by the Landlord, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope but not be limited to any and all claims or actions for wrongful death, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.4 and not this Section 9.3.

 

16


Execution Version

 

9.4 Landlord’s Environmental Indemnification.

(a) For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord’s Activities, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site by Landlord and specifically excluding to the extent the foregoing arises out of or relates to the activities of Tenant, its officers, representatives, agents, contractors, licensees, Affiliates and employees (collectively, “Tenant’s Activities”). Except for those related to Tenant’s Activities, the Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorneys, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances; (ii) any actual or alleged violation of Environmental Laws, in the case of each of subclauses (i) and (ii), where the presence, discharge or release of such Hazardous Substances or violation of Environmental Law arises or occurs (1) at, on or from the Site prior to the Ground Lease Commencement Date or (2) at, on or from the Site or any other site as a result of or relating to the Landlord’s Activities or facilities or Landlord’s Improvements, whether before, on or after the Ground Lease Commencement Date; (iii) the Landlord’s breach of the covenant set forth above in this Section 9.4; or (iv) any environmental condition of contamination on the Site or any violation of any Environmental Law with respect to the Site to the extent occurring after the Ground Lease Commencement Date and caused by the Landlord’s Activities or facilities.

(b) Tenant shall obtain at Tenant’s sole cost a Phase I, and if deemed reasonably necessary by the Tenant, a Phase II, environmental study of the Site prior to the Ground Lease Commencement Date (collectively, the “Environmental Study”) and provide a copy thereof to Landlord no later than ninety (90) days prior to the anticipated Ground Lease Commencement Date. If Tenant believes the Environmental Study shows the existence of any Hazardous Substances, Tenant shall provide notice thereof to Landlord, specifying the Hazardous Substances in question and indicating where in the Environmental Study such Hazardous Substances are noted to exist, which notice must accompany the copy of the Environmental Study delivered to Landlord within the above noted ten (10) day period for the Landlord to have any obligation to perform any Corrective Measures (as hereinafter defined). Except as provided in the following sentence, upon receipt of such notice from the Tenant the Landlord shall have a reasonable period of time to investigate and provide written notice to Tenant stating whether Landlord will undertake, at its own expense, but subject to a limit of $250,000, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority (“Corrective Measures”) and if it will not do so, stating either that the notice was not timely given (in which case Landlord shall not be responsible for undertaking Corrective Measures) or that it desires to engage at its own expense an environmental firm licensed in Louisiana to substantiate the presence of the Hazardous Substances, in which case Landlord shall have a period of thirty (30) days to obtain a report of said environmental firm. Landlord’s environmental firm shall be given reasonable and prompt access by Tenant after written notice of the date(s) said firm plans to be at the Site and shall be allowed to perform such testing as is necessary and customary for the

 

17


Execution Version

 

generation of its report. In conducting such testing, the firm will not unreasonably interfere with the construction, operation or maintenance of the Facilities and/or interfere with the Improvements by the Tenant. If the report of the environmental firm engaged by Landlord is in agreement with that of Tenant’s environmental firm as to whether the Hazardous Substances were present thereon prior to the Commencement Date of the Ground Lease, Landlord shall undertake the Corrective Measures and in doing so shall not unreasonably interfere with the construction, operation or maintenance of the Facilities and/or interfere with the Improvements by the Tenant. If the reports by the environmental firms engaged by Tenant and Landlord are not in agreement as set forth above, then the two environmental firms shall select a third firm at the joint cost of the Tenant and Landlord and the decision of said third environmental firm licensed in Louisiana shall be determinative. The foregoing procedure being the “Environmental Evaluation Procedure”. At its discretion, upon written notice to the Landlord at least sixty-five (65) days after notice to Landlord as provided above and provided Landlord has not already contracted for the performance of the Corrective Measures, commenced Corrective Measures, or given notice to Tenant that Landlord will not undertake the Corrective Measures due to untimely notice by Tenant or that the decision of the Environmental Evaluation Procedure did not substantiate that Landlord is responsible for undertaking Corrective Measures, the Tenant shall have the right to undertake such Corrective Measures and the Landlord shall reimburse the Tenant up to a total amount of $250,000 (or the Tenant may offset against Rent) for its reasonable and necessary documented actual costs incurred therefor within thirty (30) days after receipt of an invoice by the Landlord. The Party not controlling the Corrective Measures under this Section 9.4(b) shall have a reasonable right of participation in the Corrective Measures, including the right to (i) receive copies of material reports, work plans and correspondence relating to the Corrective Measures, (ii) review and comment on draft reports and work plans (and all prompt and reasonable comments shall be considered and addressed by the controlling Party in good faith), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.4(b) shall not supersede or diminish the provisions or the Landlord’s obligations under Section 9.4(a).

9.5 Survival of Indemnities. The foregoing indemnities shall, for the avoidance of doubt, be effective and in full force only following the Ground Lease Commencement Date and shall survive the Initial Term, any Extended Term and any Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

10. Insurance.

10.1 Tenant Insurance. The Tenant shall carry or cause to be carried, at its sole cost, comprehensive general public liability and property damage insurance naming Landlord and its members, directors and officers as additional insured and providing coverage for products liability, personal injury and bodily injury, and property damage, with a “broad form” endorsement that includes a contractual liability endorsement covering Tenant’s agreement to indemnify Landlord as set out in this Ground Lease, with minimum combined single limits for bodily injury and property damage of [***] per occurrence, or such other reasonable minimum limits as may be established from time to time by Landlord; (ii) Workers’ compensation insurance in accordance with the statutory requirements of the State of Louisiana; and (iii) All risk property insurance on all of Tenant’s furniture, fixtures, equipment, improvements, installed by Tenant, and other property located in, upon, or about the Site covering all risks covered by an “all risk form” policy

 

18


Execution Version

 

of fire and extended coverage insurance, with limits equal to the full replacement value thereof. Said insurance shall provide that it is primary to any other insurance Landlord may elect to carry, and contain a clause in a form acceptable to Landlord waiving all of its rights of recovery, under legal or conventional subrogation or otherwise, against Landlord, its officers, directors, members and employees. The Tenant shall notify the Landlord of any cancellation or non-renewal of a policy. Tenant’s deductible or self-insured retention shall not exceed that which is a commercially reasonable amount for the risks being insured. Each insurance policy required under this Section 10.1 and any renewal or replacement thereof shall be issued by a company that is approved to do business in the State of Louisiana and that is acceptable to Landlord in its reasonable judgment. Tenant agrees to deliver a certificate of insurance for each policy required hereunder or a renewal thereof, as the case may be, to Landlord before the term begins.

10.2 Landlord Insurance. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Site and/or any activities of the Landlord with respect to the Site in its reasonable business discretion. The Landlord may elect to be self-insured. Landlord’s election to carry or cause to be carried such insurance shall not negate or otherwise lessen Tenant’s obligations under Section 10.1.

11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. The Landlord shall not create or permit to be created or to remain in connection with the Site, or the Facilities, the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Site or upon the Landlord’s interest in the Site or upon the Tenant’s interest in its leasehold of the Site, in accordance with Section 11.2. Nothing in this Section 11.1 shall be deemed to cause Landlord to be in default hereunder in the event the Lien(s) in question were created by or due to the actions or inactions of Tenant, its officers, representatives, agents, contractors, licensees, Affiliates and employees.

11.2 Discharge of Liens.

(a) If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

 

19


Execution Version

 

(b) If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such Lien by deposit or by bonding proceedings. The non-responsible Party shall give the responsible Party written notice of the intent to do so at least ten (10) days prior to taking such action. Any amount so paid by the non-responsible Party and all costs and expenses incurred by the non-responsible Party in connection therewith, including reasonable attorneys’ fees together with interest thereon at one percent (1%) per annum above the Wall Street Journal Prime Rate of interest published from time to time in the Wall Street Journal, from the respective dates of the non-responsible Party’s making of the payment or incurring of the cost and expense, shall constitute either additional rent payable by the Tenant under this Ground Lease or an offset against Rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Site, including any liabilities, obligations and/or debts owed to laborers, vendors, brokers, materialmen, and other service providers, and then offset against the Rent any such amount(s) paid by the Tenant; provided, the Tenant has confirmed in writing with Landlord prior to doing so that Landlord does not claim a right to dispute the existence or amount of the said liabilities, obligations, responsibilities and/or debts or claim any rights against the party claiming to be due same. The Tenant shall not take any action to materially prejudice the rights of Landlord in regard to the foregoing.

12. Entry on Premises by Landlord, Etc.

Landlord and its representatives shall have the right to access and observe the Site during business hours and upon reasonable prior notice to the Tenant; provided, however, that during such time as the Site is under development or construction, such right to access and observation shall be subject to the Tenant’s reasonable discretion and any limitations or requirements of Applicable Law and Governmental Approvals and the safety protocols of Facility Contractors and others present on the Site. If and when access is granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of the Tenant that were provided to the Landlord and its representatives. Such entry on the Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions such that access to certain sections of the Site will be restricted.

 

20


Execution Version

 

13. Destruction by Fire or Other Casualty.

If the Facilities or any Improvements erected on the Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the willful misconduct of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Facilities or the Improvements. In the event that the Tenant so decides not to restore or reconstruct the Facilities or the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove any ruins or rubble remaining on the Site at the Tenant’s sole cost and expense and shall return the Site to Landlord in good order and condition.

14. Assignment; Subleasing; Right of First Refusal.

14.1 Restrictions on Landlord. The Landlord shall not assign this Ground Lease or sell the Site, in whole or in part, without the prior written consent of the Tenant, except with respect to the Tenant’s right of first refusal as set forth in Section 14.3. Any transfer inter vivos or mortis causa of any interest in Landlord shall not be a violation of this Section 14.1. This Ground Lease shall inure to the benefit of and shall be binding upon the Landlord’s permitted assigns.

14.2 Restrictions on Tenant. Subject to the provisions of Section 23, the Tenant shall not assign this Ground Lease, in whole or in part, without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least thirty (30) days prior written notice of any proposed assignment, together with a copy of the proposed assignment and such other or further information as Landlord may reasonably request. No such assignment shall release or relieve Tenant from liability under this Ground Lease prior to the date of such assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing, including to a Leasehold Lender, (ii) to a Leasehold Lender or any purchaser upon a foreclosure of a Leasehold Mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a Leasehold Mortgage, (iii) to any Affiliate or member of the Tenant, (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder and agrees in writing to attorn to Landlord as landlord under the Lease. The Tenant shall not sublease all or any portion of the Site without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned.

14.3 Right of First Refusal. During the Initial Term or any Extended Term of this Ground Lease, the Landlord may not transfer a portion of the Site and may only transfer the entire Site through a bona fide sale in exchange for a sum certain of money. If the Landlord, during the Initial Term or any Extended Term of this Ground Lease, makes a bona fide offer to sell or receives a bona fide offer that Landlord desires to accept from a third party to buy or acquire (individually and collectively a “Bona Fide Offer”) all or any portion of the Site separately or as a part of a larger parcel of which the Site is a part, the Landlord will promptly, within ten (10) Business Days of such making or receipt, give written notice to the Tenant of the terms of the Bona Fide Offer made or received, including the cash price attributable to the Site. If the sale is a tract of which the Site is a part, then the cash price attributable to the Site will be that part of the cash price

 

21


Execution Version

 

multiplied times a fraction, the denominator of which is the total number of acres in the Site and the numerator of which is the total number of acres in the larger tract to be sold. The notice shall also state the other terms and conditions of the proposed sale and the Landlord’s willingness to sell for that cash price and on those terms. Upon receiving the notice, the Tenant may exercise the right, in the manner specified below, to purchase the property described in the Bona Fide Offer at the stated cash price in the Bona Fide Offer pursuant to the process described in Sections 14.3 through 14.6. This Section 14.3 does not apply to transfers pursuant to successions or donations executed in accordance with Louisiana law.

14.4 Exercise of Right of First Refusal. If the Tenant elects to purchase the property described in the Bona Fide Offer under the provisions of Section 14.3, the Tenant must notify the Landlord of such election, doing so in writing delivered to the Landlord within twenty (20) Business Days after the date of the Landlord’s written notice to the Tenant of the Bona Fide Offer. If the Tenant elects to refuse the Bona Fide Offer, the Tenant need take no action whatsoever; further, if the Tenant fails to deliver to the Landlord a notice of the Tenant’s election within the time required for such notice, the Tenant will be deemed to have refused the Bona Fide Offer. If the Tenant refuses, or is deemed to have refused, the Bona Fide Offer, the Landlord is free to sell the property pursuant to the Bona Fide Offer subject to this Ground Lease, any New Lease, and any Leasehold Mortgage, any Non-Disturbance Agreement and continuation of the leasehold interest created by this Ground Lease and any New Lease.

14.5 Intentionally Left Blank.

14.6 Continuation of Right. If for any reason the Site is not sold by the Landlord following a Bona Fide Offer from a third-party, the right of first refusal granted and described in the preceding Sections 14.1 through 14.4 shall continue in full force and effect, on the same terms and conditions.

15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of fifteen (15) days after written notice thereof from the Landlord to the Tenant.

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15.1(a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Site or discharge from the Site shall not constitute an Event of Default.

 

22


Execution Version

 

(c) Bankruptcy. There has been instituted against the Tenant any case, proceeding or action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of the Tenant or its debts or assets, which shall not have been terminated, stayed or dismissed within ninety (90) days after commencement, or a trustee, receiver, custodian or other like official is appointed for or to take possession of all or any part of the property or assets of the Tenant, or the Tenant generally does not pay its debts as they become due; provided, however, that the Tenant shall have ninety (90) days to cure this default following the occurrence of same.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages; Termination. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default set forth in Section 15.1(a) or (b), the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the Tenant shall be liable for such reasonable damages unless such Event of Default is reasonably remedied in a timely manner and all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default, together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and payable, and all costs and expenses reasonably incurred by or on behalf of the Landlord as a result of the Event of Default, including reasonable attorneys’ fees, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective and is not valid if the Landlord does not give prior written notice to the Tenant pursuant to Section 15.1.

(b) Landlord’s Right to Cure Tenant’s Event of Default. Upon the occurrence of an Event of Default of the Tenant which is not cured or having commenced curing by the Tenant within sixty (60) days as provided in Section 15.2(b), then, subject to the prior written consent of any Leasehold Lender under Section 23, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others to cure the Event of Default. The Tenant shall be responsible for all costs, including attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord.

(c) Sole Recourse. The sole recourse of the Landlord for any damages or liabilities due hereunder shall be limited to the assets of the Tenant, without recourse individually or collectively to the assets of the members or the Affiliates of the Tenant, its lenders, or their respective directors, agents, members, shareholders, managers, employees, representatives, partners, and officers.

 

23


Execution Version

 

15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Site to the Landlord in good order and condition, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Site and may have, hold, and enjoy the Site (but by doing so it is acknowledged that Landlord is not waiving its rights to enforce the Rent or other obligations of Tenant for the remaining term of the Ground Lease); and (ii) all obligations of the Tenant hereunder for additional rent or any portion thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. ln the event of any termination, the Landlord may exercise its option to seek a successor tenant for the Site at such price and on such terms as may be immediately available. If the Landlord obtains a successor tenant during what would have been the remainder of the term of this Ground Lease, the Tenant shall receive a credit for rentals collected from said successor tenant for the remaining term of this Ground Lease. If no successor tenant is obtained, the Tenant shall be liable for Rent obligations otherwise provided for in this Ground Lease.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

16. Events of Default of the Landlord.

16.1 Landlord’s Event of Default; Right to Cure. Any failure of the Landlord to perform and/or to comply with any of its obligations, covenants, agreements, terms, or conditions contained in this Ground Lease, or there has been instituted against the Landlord any case, proceeding or action seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of the Landlord or its debts or assets, which shall not have been terminated, stayed or dismissed within ninety (90) days after commencement, or a trustee, receiver, custodian or other like official is appointed for or to take possession of all or any part of the property or assets of the Landlord, or the Landlord generally does not pay its debts as they become due, shall constitute a “Landlord’s Event of Default” hereunder; provided it continues for a period of sixty (60) days or, in the case of a bankruptcy event, ninety (90) days after notice by the Tenant to the Landlord specifying the obligation, covenant, agreement, terms or conditions of this Ground Lease alleged to have been violated and constituting a Landlord’s Event of Default to fully cure Landlord’s Event of Default.

 

24


Execution Version

 

16.2 Tenant’s Remedies; Cure. In the event of a Landlord’s Event of Default that is not fully cured under Section 16.1, in addition to all other remedies available to the Tenant, the Tenant may cancel this Ground Lease by written notice to the Landlord, seek specific performance or exercise its rights under Section 16.3. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default that is not fully cured under Section 16.1. Notwithstanding anything contained in this Section 16, the sole recourse of the Tenant for any damages or liabilities due hereunder shall be limited to the remedies under this Agreement and the assets of the Landlord and the Landlord’s interest in the Site and this Ground Lease, without recourse individually or collectively to the members of the Landlord or the Affiliates of the Landlord, or their respective directors, agents, members, shareholders, managers, employees, representatives, partners, and officers.

16.3 Tenant’s Right to Cure Landlord’s Event of Default. Upon the occurrence of a Landlord’s Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord’s Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others, purchasing the required goods or services and procuring necessary insurance, provided the time for Landlord to cure has expired and Landlord has not commenced said cure efforts. The Landlord shall be responsible for all reasonable costs including attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

17. Mutual Obligations.

17.1 Late Charges; Interest. If any Rent or other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of fifteen (15) days, such sum shall bear a late charge equal to four percent (4.0%) per annum of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

 

25


Execution Version

 

17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise (excluding, however, specific performance against the Tenant) and the exercise or beginning of the exercise by the parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by email or United States registered or certified mail, return receipt and signature requested, postage prepaid, to the parties at the following numbers and addresses:

 

To the Tenant:    Venture Global CP2 LNG, LLC
   1001 19th St North
   Suite 1500
   Arlington, VA 22209
   Attention: [***]
   Telephone: [***]
   Email: [***]
With a copy to:    Venture Global CP2 LNG, LLC
   1001 19th St North
   Suite 1500
   Arlington, VA 22209
   Attention: [***]
   Telephone: [***]
   Email: [***]
To the Landlord:    Miller Estate Leasing Company, LLC
   17 Fairway Drive
   Lake Charles, LA 70605
   Attention: [***]
   Email: [***]

 

26


Execution Version

 

With a copy to:    [***]
   Miller Estate Leasing Company, LLC
   Board Chair and CEO
   Browne Law, LLC
   3330 West Esplanade Ave South, Suite 301
   Metairie, LA 70002
   [***]

or to such other numbers or addresses as either above designated recipients may from time to time designate by written notice to the other designated recipient hereto at least fifteen (15) days in advance of an effective date stated therein.

18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mail, return receipt and signature requested, postage prepaid.

19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable possession of the Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Site during the Initial Term, any Extended Term and any Removal Period of this Ground Lease without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord. This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow compatible use of the remainder of their property adjacent to the Site and will not create or allow the creation of a visual, olfactory or auditory nuisance on said remainder of their property.

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that: (i) it is the sole owner of good title to all of the Site; (ii) the Site is subject to no Liens, privileges, encumbrances, defects in title, servitudes, easements, restrictions, dedications, leases, mineral leases, reservations or other exceptions to title; (iii) during the term hereof it shall not encumber the Site; (iv) it is authorized to make this Ground Lease for the term hereof; (v) the provisions of this Ground Lease do not and will not conflict with or violate any of the provisions of existing agreements between the Landlord and any third party; and (vi) the Landlord will deliver the Site free of all tenants and occupants and claims thereto. The Tenant shall furnish to the Landlord’s counsel a complete and up-to-date abstract of title at the Tenant’s sole expense, prior to the execution of this Ground Lease.

 

27


Execution Version

 

20. Eminent Domain.

20.1 Complete Condemnation. If, during the term hereof, the whole of the Site shall be taken by a Governmental Authority under the power of eminent domain (or the Site is sold in lieu of a taking under threat of exercise of the power of eminent domain by a Governmental Authority authorized to exercise such power, condemnation or taking), then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided, that each Party may claim for a condemnation award in accordance with Section 20.4 and all Applicable Laws. Tenant may continue to occupy the Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, paid in advance for the period that is the later of (i) from and after the actual date of the taking or (ii) from and after the date Tenant ceases to occupy the Site in whole or in part, shall be refunded to the Tenant within thirty (30) days of date. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Site from and after the date of such taking. Except as Landlord may otherwise consent in writing, Tenant and its Affiliates shall not seek, support or assist any condemnation of the Site. At Landlord’s request, Tenant at its expense shall aggressively oppose any condemnation.

20.2 Partial Condemnation. If, during the term hereof, any Governmental Authority shall, under the power of eminent domain (or a portion of the Property is sold in lieu of a taking under threat of the use of such power) makes a taking resulting in the reduction of the surface area of the Site by fifteen percent (15%) or more, or of fifteen percent (15%) or more of the value of the Facilities, the Improvements or the Landlord’s Improvements, or resulting in material interference to the Tenant’s ability to use in a commercially reasonable manner the remainder of the Site, the Facilities, the Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of the exercise of its election within one-hundred twenty (120) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2, the term hereof shall cease and terminate thirty (30) days from the date such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant for the period of time that is after the later of the termination date as determined above or the date Tenant actually ceases to occupy the Site, with said refund to be paid within thirty (30) days from the said date, and each Party may claim for a condemnation award in accordance with Section 20.4 and all Applicable Laws.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the term hereof shall continue in full force and effect, and the monthly Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete, partial or temporary taking, condemnation or other action, or threat of action, by a Governmental Authority resulting in termination of this Ground Lease and a right to compensation pursuant to Section 20.1 or Section 20.2, (a) the Tenant shall be entitled to claim from applicable Governmental Authorities in appropriate proceedings a condemnation award (or settlement) attributable to, as applicable, (i) the value of the Facilities, the Improvements, and Tenant’s fixtures and other property located on the Site so taken, plus (ii) without duplication with clause (i) above, the value of the Tenant’s leasehold estate in the Site under this Ground Lease, plus (iii) other compensation or benefits paid as a consequence of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking, including relocation damages or damages

 

28


Execution Version

 

for lost profits or loss of leasehold advantage and (b) the Landlord shall be entitled to claim from applicable Governmental Authorities in appropriate proceedings a condemnation award (or settlement) fairly attributable to, as applicable, the value of the Site, the value of any Landlord’s Improvements and unpaid rents which would have been due to the Landlord under this Ground Lease after the date of the taking or sale under threat of eminent domain. The amounts described in each of the foregoing clauses (a) and (b) shall be separate and mutually exclusive, and neither Party shall dispute or otherwise interfere with a claim made by the other Party in accordance with Applicable Laws pursuant to the foregoing.

21. Not Used

22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure; provided that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section shall govern and control.

23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage, or any agent or trustee therefor, that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant; provided, however, that no Affiliate of Tenant or of Tenant’s assigns shall be a Leasehold Lender. The term “Leasehold Mortgage” shall mean, at any point in time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Site and this Ground Lease; provided, however, that the mortgagee is not an Affiliate of Tenant or of Tenant’s assigns. It is acknowledged and agreed that, during the term of this Ground Lease, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the term of this Ground Lease, the Tenant shall provide the Landlord with written notice of the identity, contact

 

29


Execution Version

 

information and address for each Leasehold Lender (or the agent authorized to act on behalf of the Leasehold Lender), such notice to be provided to the Landlord by the Tenant within no less than thirty (30)-within which the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

23.2 Right to Perform for Tenant; Right to Cure.

(a) In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and the Landlord shall accept such performance by Leasehold Lender with the same force and effect as if furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing.

(b) If any default in the performance of an obligation of the Tenant under this Ground Lease is not susceptible to being cured by Leasehold Lender, the Landlord shall have no right to terminate this Ground Lease with respect to such default and such default shall be deemed waived for the benefit of Leasehold Lender only, provided that:

(i) Leasehold Lender shall have commenced to cure (i) any other non-payment default of the Tenant that is susceptible to being cured by Leasehold Lender and (ii) any default in the payment of any portion of Rent, in each case, within the time periods prescribed under Section 23.2(a);

(ii) Leasehold Lender (or its designee) shall have commenced to acquire the Tenant’s interest in this Ground Lease and the Site or to commence foreclosure or other appropriate proceedings under the Leasehold Mortgage within the time periods prescribed under Section 23.2(a);

(iii) if Leasehold Lender (or its designee) shall acquire the Tenant’s interest in this Ground Lease and/or the Site, Leasehold Lender (or its designee) shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition; and

 

30


Execution Version

 

(iv) if any third party shall, by foreclosure or dation en paiement under the Leasehold Mortgage or by assignment or other transfer from Leasehold Lender, acquire the Tenant’s interest in and to the Site under this Ground Lease, such third party shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by a third party with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition.

However, if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then notwithstanding any provision in this Section 23 to the contrary, the Landlord may exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’s prior written consent, and any such action taken without Leasehold Lender’s consent shall not be binding on the Tenant or Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.4 Delivery of Notices. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including, without limitation, any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been sent to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in writing to the Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’s interests in the Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including,

 

31


Execution Version

 

without limitation, the acquisition of the Tenant’s interest in this Ground Lease and the Site created thereby in a transaction described in this Section 23 or the taking of possession of the Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender; provided that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Site.

23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2, the purchaser at any sale of this Ground Lease and the interests in and to the Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including, without limitation, power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Site thereby created under any instrument of assignment or transfer in lieu of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Site thereby created.

23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, substantially all, or any part of the Site or the Tenant’s Facilities. Rent shall continue to be due and payable as set forth in this Ground Lease.

23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent domain proceeding of all, substantially all, or any part of the Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Facilities, the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Site created by this Ground Lease and the value of the leasehold improvements located on the Site, up to an amount equaling

 

32


Execution Version

 

the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Facilities and/or the Tenant’s interest in, under and to this Ground Lease; provided that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under applicable law to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this Ground Lease and as to the Site. In the event of a taking of a portion of the Site, the Rent shall be reduced pro rata based upon the portion of the Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease

 

  23.9

New Direct Lease.

(a) If this Ground Lease is canceled or terminated for any reason (except in connection with a Bankruptcy Proceeding, for which the provisions of Section 23.10 are hereby agreed upon by the Landlord and the Tenant), and provided that Leasehold Lender has (i) commenced to cure and continues diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, and (ii) cured any payment default in respect of any portion of Rent, the Landlord hereby agrees that the Landlord shall, upon Leasehold Lender’s written election within one hundred twenty (120) days of such cancellation or termination, promptly enter in a new, direct lease with Leasehold Lender (or its nominee or any other party which Leasehold Lender may designate, including without limitation, the Tenant) with respect to the Site on the same terms and conditions as this Ground Lease (a “New Lease”), it being the intention of the parties to preserve this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Said New Lease shall be superior to all rights, liens and interests intervening between the date of this Ground Lease and the granting of the New Lease and shall be free of any and all rights of the Tenant under this Ground Lease. Notwithstanding the foregoing, Landlord shall have no liability for any change in the priority of the Leasehold Mortgage, this Ground Lease or the interests in and to the Site created by this Ground Lease unless and only to the extent such change in priority is due to an act or inaction of Landlord.

(b) The Tenant and the Landlord acknowledge and agree that Leasehold Lender shall have the right to encumber such direct New Lease and the estate created thereby with a deed of trust or a mortgage (as the case may be) on the same terms and with the same lien priority as the Leasehold Mortgage, it being the intention of the parties to preserve the priority of the Leasehold Mortgage, this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Notwithstanding the foregoing, Landlord shall have no liability for any change in the priority of the Leasehold Mortgage, this Ground Lease or the interests in and to the Site created by this Ground Lease unless and only to the extent such change in priority is due to an act or inaction of Landlord. If this Ground Lease is

 

33


Execution Version

 

rejected, cancelled or terminated for any reason and Leasehold Lender, its nominee or a designee of Leasehold Lender enters into a direct lease with the Landlord with respect to the Site, the Landlord hereby agrees that it will execute such documents as Leasehold Lender may require in order to ensure that the new direct lease provides for customary leasehold mortgagee protections, including without limitation, protections similar to those contained herein.

23.10 Bankruptcy. In the event of a proceeding under the United States Bankruptcy Code (Title 11 U.S.C.) as now or hereafter in effect (a “Bankruptcy Proceeding”):

(a) If this Ground Lease is rejected in connection with a Bankruptcy Proceeding by the Tenant or a trustee in bankruptcy (or other party to such proceeding) for the Tenant, such rejection shall be deemed an assignment by the Tenant to the Leasehold Lender of the Tenant’s Property and all of the Tenant’s interest under this Ground Lease, and this Ground Lease shall not terminate and the Leasehold Lender shall have all rights and obligations of the Tenant as if such Bankruptcy Proceeding had not occurred, unless Leasehold Lender shall reject such deemed assignment by notice in writing to the Landlord within thirty (30) days following rejection of this Ground Lease by the Tenant or the Tenant’s trustee in bankruptcy. If any court of competent jurisdiction shall determine that this Ground Lease shall have been terminated notwithstanding the terms of the preceding sentence as a result of rejection by the Tenant or the trustee in connection with any such proceeding, the rights of Leasehold Lender to a New Lease from the Landlord pursuant to Section 23.9 hereof shall not be affected thereby.

(b) In the event of a Bankruptcy Proceeding against the Landlord:

(i) If the bankruptcy trustee, the Landlord (as debtor-in-possession) or any party to such Bankruptcy Proceeding seeks to reject this Ground Lease pursuant to United States Bankruptcy Code §365(h)(1), the Tenant shall not have the right to treat this Ground Lease as terminated except with the prior written consent of Leasehold Lender and the right to treat this Ground Lease as terminated in such event shall be deemed assigned to Leasehold Lender, whether or not specifically set forth in the Leasehold Mortgage, so that the concurrence in writing of the Tenant and the Leasehold Lender shall be required as a condition to treating this Ground Lease as terminated in connection with such Bankruptcy Proceeding.

(ii) Unless this Ground Lease is treated as terminated in accordance with Section 23.10(b)(i), then this Ground Lease shall continue in effect upon all the terms and conditions set forth herein, including Rent, but excluding requirements that are not then applicable or pertinent to the remainder of the term of this Ground Lease. The lien of the Leasehold Mortgage shall extend to the continuing possessory rights of the Tenant following such rejection with the same priority as it would have enjoyed had such rejection not taken place.

 

34


Execution Version

 

  23.11

Estoppel Certificates; Non-Disturbance Agreements.

(a) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel”) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under this Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant thereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that each of this Ground Lease and the Non-Disturbance Agreement, true, correct copies of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, have not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Landlord’s power and authority to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, and any Non-Disturbance Agreement, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which Landlord is a party, (xiii) that there are no agreements to which Landlord is a party, judgments, proceedings involving Landlord as a party, liens, or encumbrances affecting the Site, other than those filed in the public records of Cameron Parish, Louisiana and those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the Landlord Estoppel, the present lessor under this Ground Lease and owns good and merchantable title to the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (xix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

 

35


Execution Version

 

(b) Within fifteen (15) days following Leasehold Lender’s or the Landlord’s written request, the Tenant shall provide Leasehold Lender with an estoppel certificate (the “Tenant Estoppel”) which shall certify to such requesting Leasehold Lender (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Landlord of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Landlord of any other conditions required under this Ground Lease, (iii) as to any existing default of the Landlord under this Ground Lease, or alternatively that the Landlord is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Landlord hereunder, and as to any existing event or condition in existence as of the date of the Tenant Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Tenant to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Tenant, (v) that this Ground Lease, a true and correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Tenant’s power and authority to execute the Tenant Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Tenant asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Tenant from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties, or other sums, whether or not constituting rent, due and owing as of the date of the Tenant Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which the Tenant is a party (other than those set forth on a schedule to the Tenant Estoppel), (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Tenant Estoppel, (xiv) that the Tenant is, as of the date of the Tenant Estoppel, the present lessee under this Ground Lease and holds a valid leasehold interest in the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Tenant has not assigned, sublet, hypothecated, leased, or otherwise transferred it interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Tenant’s interest in the Site, other than those set forth on a schedule to the Tenant Estoppel, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Tenant is a party or by which the Tenant is otherwise bound affecting the Tenant’s interest in and to the Site, (xvii) that the Tenant has not commenced any action or sent any notice to the Landlord for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Tenant is not, as of the date of the Tenant Estoppel, entitled to terminate, cancel, modify, or surrender this Ground Lease, and (xviii) as to such other matters related to this Ground Lease as such Leasehold Lender may reasonably determine from time to time.

 

36


Execution Version

 

(c) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall enter into a non-disturbance agreement with Leasehold Lender or its designee, in the form attached hereto as Exhibit 5 (a “Non-Disturbance Agreement”).

23.12 No Termination by Confusion. There shall be no termination of this Ground Lease or any interest in this Ground Lease by confusion by reason of the fact that this Ground Lease or such interest therein, may be directly or indirectly held by or for the account of any person who also holds an ownership interest in the Site, nor shall this Ground Lease terminate by confusion by reason of the fact that all or any part of the Site may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any ownership interest in the Site or any interest of the Landlord under this Ground Lease.

23.13 Landlord’s Recognition of Tenant. The Landlord hereby recognizes the Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that the Tenant acquired its interest in this Ground Lease and in and to the Site in accordance with the terms of this Ground Lease.

23.14 Agreement to Amend. The Landlord recognizes the importance of the Tenant’s ability to obtain Leasehold Mortgages, and that the provisions of this Ground Lease may be subject to the approval of a Leasehold Lender. If any Leasehold Lender should require, as a condition to such financing, any reasonable modifications of this Ground Lease, whether for purposes of clarifying the provisions of this Ground Lease or to include provisions then customary for leasehold financing transactions, the Landlord agrees to execute the appropriate amendments to this Ground Lease; provided, however, that no such modification shall, to the detriment of the Landlord, impair any of the Landlord’s rights, as reasonably determined by the Landlord or increase any of the Landlord’s obligations, as reasonably determined by the Landlord, under this Ground Lease.

23.15 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

23.16 Subordination of Landlord’s Lien. The Landlord hereby subordinates any lien or privilege it may have on any movables found from time to time in or upon the Site, including without limitation, the Landlord’s privileges pursuant to La. Civil Code articles 2707, et seq., to any Leasehold Lender’s rights under this Section 23 and the lien of any Leasehold Mortgage.

24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

 

37


Execution Version

 

24.2 Successors. The covenants, agreements, terms, provisions, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties hereto.

24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

24.6 No Oral Change or Termination. Except as expressly set forth in the Option Agreement, this Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties hereto with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

 

38


Execution Version

 

24.9 Litigation. In case of any litigation between the Parties hereto regarding the subject matter hereof, the losing Party shall pay all reasonable costs and expenses (including reasonable attorneys’ fees) of the prevailing Party. The venue of any litigation in state or federal court shall be solely in Cameron Parish or the Western District of Louisiana.

24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

24.11 Authority. Each of the Landlord and the Tenant represents and warrants that it has the authority to enter into this Ground Lease, and that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date, (a) the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 3, evidencing its authority to execute and perform under this Ground Lease and (b) the Landlord shall deliver to the Tenant a resolution in the form attached hereto as Exhibit 4, evidencing its authority to execute and perform under this Ground Lease.

24.12 Brokers and/or Real Estate Agents. Each of the Landlord and the Tenant represents, acknowledges and agrees that it is not represented by any real estate broker/agent and that it is not responsible for payment of any commissions to any real estate brokers/agents in connection with this Ground Lease other than that Landlord has been represented by Derek Pelloquin as its broker pursuant to the Non-Exclusive Broker Listing Agreement for Commercial/Industrial Property Surface Lease.

24.13 Legal Relationships; Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. There is no third party beneficiary of this Ground Lease, except as provided in Section 23.15 and any rights of a Leasehold Lender as provided herein.

24.14 Further Assurances. In connection with this Ground Lease and the transactions contemplated hereby, each Party shall execute and deliver any additional documents and instruments and perform any additional acts that may be necessary or appropriate to effectuate and perform the provisions of this Ground Lease and those transactions, including in connection with the requests of any Financing Parties or Leasehold Lender.

24.15 No Waiver or Surrender. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Site and no agreement to accept a surrender of the Site shall be valid unless it is in writing and signed by the Landlord.

24.16 Memorandum of Lease. The Parties hereto agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’s interest hereunder; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease.

[Remainder of page left intentionally blank; signatures on following pages]

 

39


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

           LANDLORD:
    MILLER ESTATE LEASING COMPANY, LLC

/s/ Denise Dauterive

    By:  

/s/ David L. Browne

WITNESS Denise Dauterive    

Name: David L. Browne

Title: Board Chair & CEO

/s/ Claire Hyer

   
WITNESS Claire Hyer    

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Jefferson and State of Louisiana, personally came and appeared David L. Browne, who, after being sworn by me, did execute this agreement on the 12th day of October, 2023 at Metairie, State of Louisiana.

     /s/ Cynthia M. Cimino     

NOTARY PUBLIC

 

           TENANT:

/s/ Tracy Pelt

    VENTURE GLOBAL CP2 LNG, LLC
WITNESS Tracy Pelt    

/s/ Jeff Layman

    By:  

/s/ Keith Larson

WITNESS Jeff Layman     Name: Keith Larson
    Title: Secretary

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 6th day of October, 2023 at Arlington, State of Virginia.

     /s/ Michael E. Millan     

NOTARY PUBLIC

 

1


Execution Version

LIST OF EXHIBITS

 

Exhibit 1    Legal Description of the Site
Exhibit 2    Site Survey
Exhibit 3    Tenant’s Resolution
Exhibit 4    Landlord’s Resolution
Exhibit 5    Form of Non-Disturbance Agreement

 

1


EXHIBIT 1

LEGAL DESCRIPTION OF THE SITE

PARCEL “R”

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND ONE HALF INCH DIAMETER IRON PIPE; THENCE S.89°23’14”E., A DISTANCE OF 4,151.02 FEET TO THE NORTHWEST CORNER OF SECTION 8, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°56’33”W; A DISTANCE OF 330.15 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°56’33”W., A DISTANCE OF 759.51 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.01°19’17”W., A DISTANCE OF 84.97 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.01°19’50”W., A DISTANCE OF 814.24 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°59’32”W., A DISTANCE OF 785.80 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°58’57”W., A DISTANCE OF 930.52 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.01’11’40”W., A DISTANCE OF 624.74 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR, OFFSET 4.99’ S.89°40’22”E. OF TRUE POSITION, SAID POINT BEING THE POINT OF BEGINNING; THENCE S.89°02’21”E., A DISTANCE OF 453.94 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE S.00°57’11”W., A DISTANCE OF 2,559.83 FEET TO A POINT ALONG THE NORTH LINE OF STATE CLAIMED LAND, SAID POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.77°08’31”W., A DISTANCE OF 465.13 FEET TO THE INTERSECTION OF AN OCCUPATION LINE BEING REPRESENTED BY AN EXISTING FENCE AND SAID NORTH LINE OF STATE CLAIMED PROPERTY, SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 4.16’ S.00°27’34”W. OF TRUE POSITION; THENCE N.00°27’34”E., A DISTANCE OF 99.32 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°54’35”E., A DISTANCE OF 1,414.17 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°54’35”E., A DISTANCE OF 1,414.17 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.01°19’17”W., A DISTANCE OF 440.92 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°39’53”E., A DISTANCE OF 565.19 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.01011’40”E., A DISTANCE OF 151.35 FEET TO THE POINT OF BEGINNING.

 

2


SAID DESCRIBED PARCEL, CONTAININGL, l84,984.88 SQUARE FEET OR 27.2035 ACRES, IS SITUATED IN SECTION 8, TOWNSHlP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “R”.

-AND-

PARCEL “T”

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE HALF INCH DIAMETER IRON PIPE; THENCE S.89°23’14”E., A DISTANCE OF 4,151.02 FEET TO THE NORTHWEST CORNER OF SECTION 8, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°56’33” W., A DISTANCE OF 330.15 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°56’33”W., A DISTANCE OF 759.51 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.01°19’17”W., A DISTANCE OF 84.97 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.0l°19’50”W., A DISTANCE OF 814.24 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°59’32”W., A DISTANCE OF 785.80 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°58’57”W., A DISTANCE OF 930.52 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DlAMETER IRON PIPE; THENCE S.0l°11’40”W., A DISTANCE OF 624.74 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR, OFFSET 4.99’ S.89°40’22”E. OF TRUE POSITION; THENCE S.89°02’21”E., A DISTANCE OF 453.94 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE S.89°02’21”E. A DISTANCE OF 471.18 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR, SAID POINT BEING THE POINT OF BEGINNING; THENCE S.89°02’2l”E., A DISTANCE OF 491.73 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE S.89°02’21”E., A DISTANCE OF 438.47 FEET TO A POINT ALONG THE EAST LINE OF SECTION 9, TOWNSHIP 15 SOUTH RANGE 9 WEST, SAID POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE S.89°03’23”E., A DISTANCE OF 73.70 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE S.89°03’23’‘E., A DISTANCE OF 539.15 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE S.89°03’23”E., A DISTANCE OF 302.45 FEET TO A POINT ALONG THE EAST LINE OF SECTION 10, TOWNSHIP 15 SOUTH RANGE 10 WEST, SAID POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE S.89°03’23”E., A DISTANCE OF 271.35 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE S.89°03’23”E., A DISTANCE OF 635.71 FEET TO A POINT ALONG THE EAST LINE OF SECTION 11, TOWNSHIP 15 SOUTH RANGE 9 WEST, SAID POINT BEING MARKED BY

 

3


A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.01°24’42”W., A DISTANCE OF 910.93 FEET ALONG THE EAST LINE OF SAID SECTION 11 TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.86°31’4l”W., A DISTANCE OF 24.16 FEET TO A POINT BEING MARKED BY A FOUND ONE INCH DIAMETER IRON PIPE; THENCE S.02°03’31”W., A DISTANCE OF 627.25 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.80°02’4l”E., A DISTANCE OF 31.78 FEET TO A POINT ALONG THE EAST LINE OF SAID SECTION 11 BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.0l°24’42”W., A DISTANCE OF 291.66 FEET TO THE INTERSECTION OF THE EAST LINE OF SAID SECTION 11 AND THE NORTH LINE OF STATE CLAIMED LAND, SAID POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.76°42’44”W., A DISTANCE OF 640.79 FEET ALONG THE NORTH LINE OF SAID STATE CLAIMED LAND TO A POINT; THENCE S.76°42’44”W., A DISTANCE OF 279.95 FEET ALONG THE NORTH LINE OF SAID STATE CLAIMED LAND TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE AND A FOUND HALF INCH DIAMETER IRON BAR, OFFSET 3.94’ N.l2°37’46”W. OF TRUE POSITION; THENCE S.77°43’2l”W., A DISTANCE OF 310.70 FEET ALONG THE NORTH LINE OF SAID STATE CLAIMED LAND TO A POINT; THENCE S.77°43’21”W., A DISTANCE OF 553.85 FEET ALONG THE NORTH LINE OF SAID STATE CLAIMED LAND TO A POINT; THENCE S.77°43’2l”W., A DISTANCE OF 75.71 FEET ALONG THE NORTH LINE OF SAID STATE CLAIMED LAND TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE AND A FOUND FOUR INCH DIAMETER TRANSITE PIPE, OFFSET 1.50’ N.33°43’28”W. OF TRUE POSITION; THENCE S.80°11’10”W., A DISTANCE OF 446.33 FEET ALONG THE NORTH LINE OF SAID STATE CLAIMED LAND TO A POINT; THENCE S.80°11’10”W., A DISTANCE OF 500.54 FEET TO THE INTERSECTION OF THE NORTH LINE OF SAID STATE CLAIMED LAND AND AN OCCUPATION LINE BEING REPRESENTED BY AN EXISTING FENCE, SAID POINT ALSO BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE AND A FOUND ONE INCH DIAMETER IRON BAR, OFFSET 2.56’ N.22°52’53”W. OF TRUE POSITION; THENCE N.00°57’11”E., A DISTANCE OF 2,443.94 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 5,893,823.07 SQUARE FEET OR 135.3036 ACRES, IS SITUATED IN SECTIONS 9, 10, & 11, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “T” ON THE HERETO ATTACHED PLAT.

 

4


EXHIBIT 2

SITE SURVEY

[Omitted]


EXHIBIT 3

TENANT’S RESOLUTION

[Omitted]


EXHIBIT 4

LANDLORD’S RESOLUTION

[Omitted]


EXHIBIT 5

FORM OF NON-DISTURBANCE AGREEMENT

[Omitted]

Exhibit 10.60

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

 

STATE OF LOUISIANA

PARISH OF CAMERON

  GROUND LEASE AGREEMENT   

(124.5 Acres)

This GROUND LEASE AGREEMENT (this “Ground Lease”) is executed and effective as of October 12, 2023 (the “Ground Lease Commencement Date”), by and between Venture Global CP2 LNG, LLC, a Delaware limited liability company (the “Tenant”), and Charlotte Ann LaBove and Carlotta Ann Savoie (collectively, the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as a “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Cameron Parish, Louisiana, which comprises approximately one hundred twenty-four and one-half (124.5) acres; and

WHEREAS, the Tenant wishes to lease land owned by the Landlord for the construction, development and operation of a natural gas liquefaction facility and liquefied natural gas (“LNG”) export terminal (the “Facilities”) and other uses permitted by this Ground Lease; and

WHEREAS, in accordance with the above, the Tenant has executed this Ground Lease and offers fair value to the Landlord as cause and consideration for this Ground Lease.

NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this Ground Lease, and the Parties herein covenant and agree as follows:

1. Definitions and Interpretation.

As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

Adjustment Period” has the meaning set forth in Section 4.1(c).

Affiliate” means, in respect of any Person, any other Person controlled by, controlling or under common control with such first Person. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of thirty percent (30%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.

Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Site.

 

1


Bankruptcy Proceeding” has the meaning set forth in Section 23.10.

Bona Fide Offer” has the meaning set forth in Section 14.3.

Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in the State of New York are authorized or required by law to close.

Consumer Price Index” has the meaning set forth in Section 4.2.

Corps” has the meaning set forth in Section 8.3(a).

Corrective Measures” has the meaning set forth in Section 9.4(b).

CPI Adjustment” has the meaning set forth in Section 4.1.

CPI Disagreement Notice” has the meaning set forth in Section 4.2.

CPI Notice” has the meaning set forth in Section 4.2.

CPI Percentage Increase” has the meaning set forth in Section 4.2.

Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Law relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

Event of Default” has the meaning set forth in Section 15.1.

Extended Term” has the meaning set forth in Section 3.2.

Facilities” has the meaning set forth in the Recitals hereof.

Facility Contractor” means any Person (other than the Tenant or its Affiliate) that is party to a Facility Contract.

Facility Contracts” means, collectively, the contracts entered into by the Tenant in connection with the design, engineering, construction, equipment procurement, testing, commissioning, operation and maintenance of the Facilities, the Site and/or the Improvements.

 

2


Fair Market Value” means the value determined pursuant to the process set forth in Section 14.5.

Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Facilities, the Improvements, the Site, or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders.

First Appraiser” has the meaning set forth in Section 14.5.

Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, droughts, floods, washouts, explosions, breakage or accident or necessity of repairs to machinery or equipment or lines of pipe; (ii) weather related events affecting an entire geographic region; (iii) acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, terrorism, discovery of burial grounds or human remains or legally protected artifacts, insurrections or wars; (iv) the failure or interruption of performance by the Tenant’s engineering, procurement and construction contractor or any subcontractors of such contractor to the extent caused by an event of Force Majeure under this Ground Lease; (v) the failure or interruption of performance by the Tenant’s suppliers by reason of such supplier’s valid declaration of an event that would constitute an event of force majeure under the Tenant’s contract with such supplier; and (vi) governmental actions such as necessity for compliance with any court order, law, statute, ordinance, regulation, or policy having the effect of law promulgated by a Governmental Authority having jurisdiction, or that restrict the Tenant’s ability to reasonably construct and/or operate the Facilities or the Improvements or any delay in issuance or effectiveness of any Governmental Approval that has been properly applied for by the Tenant that is required to construct and/or operate the Facilities or the Improvements.

Governmental Approval” means any authorization, waiver, consent, approval, license, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority.

Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

Ground Lease” has the meaning set forth in the Preamble hereof.

Ground Lease Commencement Date” has the meaning set forth in the Preamble hereof.

 

3


Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

Hazardous Substances Law” means any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent it relates to the handling of and exposure to hazardous or toxic materials or similar substances.

Improvements” means any and all improvements made by Tenant, in its sole discretion, to the Site, including but not limited to, improvements relating to the loading, unloading, handling, treatment, processing, producing, transporting, distributing, selling, metering and/or storing of (i) natural gas, natural gas liquids, and other natural gas products, derivatives and by-products and (ii) other petroleum and hydrocarbon liquids, gases, products, derivatives and by-products, including but not limited to (A) the importation, regasification, production, exportation, liquefaction, refinement, enhancement, other treatment and transportation (including by ship, pipeline, truck or rail) of LNG, and LNG by-products and additives and (B) the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of any improvements, component parts and other constructions, fixtures, facilities, equipment and/or appurtenances (including natural gas pipelines, natural gas liquids extraction, processing and delivery facilities, acid gas removal units, natural gas liquefaction trains, LNG regasification facilities, and other treatment facilities, cryogenic pipelines, LNG storage tanks, petroleum and other hydrocarbon liquids storage facilities, nitrogen

 

4


storage and processing facilities, power generation and transmission infrastructure, marine, rail and trucking receipt, delivery and servicing facilities (including piers, marine terminals, bulkheads, wharfs, docks, inlets, wetslips, moonpools, moorings, jetties, and loading and unloading equipment), and other utilities and facilities (including berms, open space, security fencing, control rooms, offices, warehouses, parking and yards), in each case, necessary, ancillary or desirable to the Tenant in connection with the foregoing.

Initial Term” has the meaning set forth in Section 3.1.

Landlord” has the meaning set forth in the Preamble hereof.

Landlord Estoppel” has the meaning set forth in Section 23.11(a).

Landlord Indemnitee” has the meaning set forth in Section 9.1.

Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, affiliates, invitees, agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Site and/or Landlord’s Improvements.

Landlord’s Event of Default” has the meaning set forth in Section 16.1.

Landlord’s Improvements” has the meaning set forth in Section 6.1.

Lease Year” means a period of twelve (12) consecutive full calendar months. The first Lease Year shall begin on the Ground Lease Commencement Date. Each succeeding Lease Year shall commence upon the anniversary of the first day of the previous Lease Year.

Leasehold Lenders” has the meaning set forth in Section 23.1.

Leasehold Loan” has the meaning set forth in Section 23.1.

Leasehold Mortgage” has the meaning set forth in Section 23.1.

Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

LNG” has the meaning set forth in the Recitals hereof.

Minerals” has the meaning set forth in Section 8.3(b).

New Lease” has the meaning set forth in Section 23.9(a).

Non-Disturbance Agreement” has the meaning set forth in Section 23.11(c).

 

5


Option Agreement” means the Real Estate Lease Option Agreement among Charlotte Ann LaBove, Carlotta Ann Savoie and Tenant (as successor in interest to Cameron Land Ventures, LLC, dated as of June 30, 2020.

Party” or “Parties” has the meaning set forth in the Preamble hereof.

Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

Property Taxes” means all real (immovable) and personal (movable) property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

Removal Period” means the period of time that is required by Tenant to remove any and all of Tenant’s Property, including the Facilities and/or Improvements, from the Site in accordance with Section 7.1.

Rent” has the meaning set forth in Section 4.1.

Second Appraiser” has the meaning set forth in Section 14.5.

Site” means the real (immovable) property of approximately one hundred twenty-four and one-half (124.5) acres described in the legal description set forth in Exhibit 1, and illustrated by the Survey Map attached as Exhibit 2, upon which the Facilities and any Improvements will be located and which real (immovable) property is owned by the Landlord.

Surface Waiver” has the meaning set forth in Section 8.3(b).

Survey Map” means the ALTA survey of the Site, dated April 9, 2020, by Lonnie G. Harper & Associates, Inc., attached as Exhibit 2.

Tenant” has the meaning set forth in the Preamble hereof.

Tenant Estoppel” has the meaning set forth in Section 23.11(b).

Tenant Indemnitee” has the meaning set forth in Section 9.3.

Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Site by or on behalf of the Tenant, including the Facilities and any Improvements.

 

6


Third Appraiser” has the meaning set forth in Section 14.5.

1.2 Interpretation. Unless the context otherwise requires:

(a) Words singular and plural in number will be deemed to include the other and pronouns having a masculine or feminine gender will be deemed to include the other;

(b) Any reference to this Ground Lease or any other contract or agreement in respect of the Site means such agreement and all schedules, exhibits and attachments thereto as may be amended, supplemented or otherwise modified and in effect from time to time, and shall include a reference to any document which amends, modifies or supplements it, or is entered into, made or given pursuant to or in accordance with its terms;

(c) The terms “hereof,” “herein,” “hereby,” “hereto” and similar words refer to this entire Agreement and not any particular Section, subsection or other subdivision of, or Exhibit, appendix or schedule to, this Ground Lease;

(d) The terms “include” and “including” shall be construed as being at all times followed by the words “without limitation” or “but not limited to” unless the context specifically indicates otherwise;

(e) References to “Article,” “Section” or “Exhibit” are to this Ground Lease unless specified otherwise;

(f) References to any law, statute, rule, regulation, notification or statutory provision (including Applicable Laws) shall be construed as a reference to the same as it may have been, or may from time to time be, amended, modified or re-enacted;

(g) References to any Person shall be construed as a reference to such Person’s successors, heirs and permitted assigns; and

(h) The word “or” will have the inclusive meaning represented by the phrase “and/or”.

2. Ground Lease Premises.

2.1 Date. The date of this Ground Lease is the Ground Lease Commencement Date.

2.2 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of the rents and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does lease to the Tenant and the Tenant hereby leases from the Landlord, the Site and Landlord’s Improvements.

 

7


2.3 Servitudes. In addition, the Landlord shall without cost to the Tenant, grant from time to time to the Tenant and others designated by the Tenant (including any Affiliate of the Tenant) any servitudes and rights of way for access and electricity, communications, gas, water, sewer and other utility lines, products and materials from and to the Site over land and waterways sufficient to access adjacent lands owned by the Landlord and to permit the Tenant to accomplish its purposes in connection with the Improvements and the Facilities.

3. Term

3.1 Initial Term. The initial term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on the thirtieth (30th) anniversary of the Ground Lease Commencement Date (the “Initial Term”).

3.2 Extensions.

(a) In consideration of and conditioned upon there being no uncured Event of Default on the part of the Tenant at the time an option is exercised, the Landlord hereby grants unto the Tenant the option to lease the Site for four (4) additional ten (10) year terms. If the extension option is exercised in accordance with Section 3.2(b), the first of said additional terms shall commence upon the expiration of the Initial Term and extend for a period of ten (10) years and each of said additional terms shall commence upon the expiration of the then-current additional term and extend for a period of ten (10) years. Each of such additional terms is referred to herein as an “Extended Term” and, collectively, the Initial Term and any Extended Terms are referred to herein as the “Term”.

(b) The option to extend this Ground Lease of the Site as set forth in Section 3.2(a) must be exercised in each case, if at all, by written notice from the Tenant to the Landlord on or before the date that is three (3) months prior to the expiration of the Initial Term or the then-current Extended Term, as applicable. The failure of the Tenant to timely exercise the first Extended Term or any subsequent Extended Term shall automatically terminate the right of the Tenant to exercise its option to lease the Site in any subsequent Extended Term.

(c) All the terms and conditions of this Ground Lease shall be applicable to any Extended Term and the Rent payable by the Tenant for any Extended Term shall be in accordance with the provisions set forth in Article 4.

4. Compensation.

4.1 Rent. Commencing upon the Ground Lease Commencement Date, the initial rent for the Site (“Rent”) shall be [***] per annum, payable in equal installments of [***] per month, adjusted upward every five (5) years thereafter during the Term by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment during any Adjustment Period (as defined below) of greater than [***]. The period of time from the Ground Lease Commencement Date through the date five years thereafter, and each five (5) year period thereafter shall be defined herein as an “Adjustment Period.” Any upward adjustment based on a CPI

 

8


Percentage Increase (as defined below) to any payment under this Ground Lease shall hereinafter be referred to as a “CPI Adjustment.” Such Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month; provided, however, that: (x) the first payment of Rent shall be on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first day of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; (y) the first payment of Rent due upon the commencement of any new Adjustment Period will be owed and paid one month after the commencement of that Adjustment Period in order to permit the Tenant to calculate the CPI Percentage Increase, as set forth below; and (z) the last payment of Rent shall be in a prorated amount for the period of time between the immediately preceding first day of the month and the last day of the Term.

4.2 CPI Adjustment. If the CPI Percentage Increase (as defined below) is more than [***] for the relevant Adjustment Period, then the Rent payable during that Adjustment Period shall be adjusted upward by a percentage equal to the CPI Percentage Increase (as defined below) applicable to such Adjustment Period, but not to exceed an adjustment during any Adjustment Period of greater than [***]. The term “Consumer Price Index” shall mean the unadjusted Consumer Price Index for All Urban Workers, U.S. City Average, All Items, 1982-84=100, calculated and published by the United States Department of Labor, Bureau of Labor Statistics. The “CPI Percentage Increase” shall mean, with respect to any Adjustment Period, [***]. For the avoidance of doubt, no CPI Adjustment shall be made to any payment due under this Ground Lease for any Adjustment Period if the result of such CPI Adjustment would be to (a) reduce the amount of such payment to an amount that is less than the amount of such payment due for the immediately preceding Adjustment Period or (b) to raise the amount of such payment to an amount that is greater than [***]. For illustrative purposes only, [***]. The CPI Percentage Increase for any Adjustment Period shall be calculated by the Tenant, and the Tenant shall deliver written notice to the Landlord describing such calculation in reasonable detail (a “CPI Notice”) no later than thirty (30) days after the commencement of any Adjustment Period. If the Landlord disagrees with the Tenant’s calculation of the CPI Percentage Increase, then the Landlord shall deliver to the Tenant written notice, describing the basis for such disagreement in reasonable detail (a “CPI Disagreement Notice”), not later than thirty (30) days after delivery of the CPI Notice. If the Landlord fails to deliver a CPI Disagreement Notice within thirty (30) days after delivery of any CPI Notice, then the Landlord shall be conclusively deemed to have agreed with the calculation of the CPI Percentage Increase set forth in such CPI Notice.

 

9


4.3 Additional Consideration for Landlord’s Improvements. Without limiting the other provisions of this Article 4, the Landlord acknowledges that, on or prior to the Ground Lease Commencement Date, the Tenant made a one-time payment of [***] to the Savoie Landlord (or any other individual or entity designated by the Landlord) as sole and exclusive consideration for the Landlord’s Improvements.

4.4 Business Days. If the day on which any amount hereunder is due and payable is not a Business Day, such amount shall not be due and payable until the next following Business Day.

4.5 Place of Payment. Except as otherwise provided herein, Rent shall be payable by check or wire transfer at the following address or via wire instructions provided by the Landlord to the Tenant in writing, or to such other place as the Landlord may specify and the Tenant deem acceptable, as hereinafter provided, from time to time:

[***]

[***]

[***]

[***]

[***]

[***]

5. Net Lease; Taxes and Utility Expenses.

5.1 Net Lease. This Ground Lease is a net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs, if any, of every kind and nature whatsoever relating to the Site except as expressly otherwise provided in this Ground Lease.

5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and Governmental Approval fees applicable to the Site during the Term.

(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on or related to, the Improvements, but not the underlying real property comprising the Site during the Term (prorated on the basis of a 365-day year to account for any fractional portion of a fiscal tax year included in at the commencement or expiration of the Term). The Landlord shall promptly provide all Property Tax bills to the Tenant when they become available. Upon the latter of (i) one (1) month after receipt of such Property Tax bill from the Landlord or (ii) the due date of any such Property Taxes, the Tenant shall provide the Landlord with reasonable written evidence from the Cameron Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided, that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

 

10


(c) The Landlord shall provide written notice to the Tenant of its receipt of any oral or written notice of any audit, examination, claim or assessment relating to Property Taxes on or related to the Improvements within ten (10) Business Days following receipt of such notice. At the Tenant’s election, the Landlord shall initiate a claim and commence proceedings with the appropriate Governmental Authority to contest, resolve, appeal, defend and settle any such audit, examination, claim or assessment, as applicable, all at the Tenant’s direction. The Landlord and the Tenant shall otherwise reasonably cooperate to minimize assessed value of the Improvements and underlying real property, including through coordination with the Cameron Parish Tax Collector’s Office.

5.3 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost, electricity, telephone, water, sewerage, gas, and other utility services to the Site; provided, however, the Landlord shall cooperate, and to the extent reasonably needed, facilitate the contracting of any easements, servitudes and/or rights of way, and grant easements, servitudes and rights of way in accordance with Section 2.3, as required by the Tenant for such utility connections and/or services.

6. Tenant and Landlord Improvements.

6.1 Landlord’s Improvements. “Landlord’s Improvements” are any and all improvements to the immovable property of the Site and any and all movable property in existence on the Site at the time of the Ground Lease Commencement Date. There are no Landlord’s Improvements except: (a) one 16 x 72 single-wide trailer, (b) one approximately 60x60 ft agricultural barn, (c) one approximately 55x50 ft agricultural barn and (d) one approximately 24x24 ft accessory building/shop. For the avoidance of doubt, as of the expiration of the Term or earlier termination of this Ground Lease, the Tenant shall have no obligation to restore, return or provide any further consideration for any Landlord’s Improvements.

6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install on the Site, any Improvements during the Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. During the Term, the Tenant shall be permitted to make any changes, improvements or alterations to the Site, including, without limitation, the Facilities, the Landlord’s Improvements and any Improvements to the Site, as long as the changes, alterations and/or Improvements comply with Applicable Laws.

6.3 Governmental Approvals. The Landlord will cooperate and assist (and never oppose) the Tenant in obtaining any and all Governmental Approvals deemed necessary by the Tenant for the Facilities and all other Improvements to the Site, including with respect to Governmental Approvals from the Federal Energy Regulatory Commission and the Department of Energy. The Landlord will hereafter continue to be obligated to execute appropriate documentation to waive its right to require wetlands mitigation to be completed on the Site or other real (immovable) property owned by the Landlord, in such form as necessary to allow the Tenant to complete such wetlands mitigation at locations other than other real (immovable) property

owned by the Landlord.

 

11


6.4 Tenant’s Property. Tenant’s Property shall at all times be and remain the sole property of the Tenant.

6.5 Maintenance of Improvements.

(a) Tenant’s Obligation to Maintain. During the Term, the Tenant will keep in reasonably good state of repair the Facilities, the Improvements, open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Site by the Tenant, and the Tenant will, in its sole discretion and cost, repair such property as often as may be necessary in order to keep the Facilities and the Improvements in reasonably good repair and condition, except as set forth in Section 6.5(b).

(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease, the Landlord has no obligation to maintain the Site, Improvements and/or Landlord’s Improvements (if any) during the Term. The Landlord further agrees that there will be no Landlord improvements on the Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

7. Tenant’s Surrender of Site.

7.1 Surrender at End of Ground Lease. Subject to Section 6.4 and subject and subordinate to Section 23 and the rights of any Leasehold Lender under any Leasehold Mortgage, the Tenant shall and will on the last day of the Term, surrender and deliver the Site to the Landlord, in good condition as is reasonably practicable (except as provided in Section 6.5 or Section 13), excepting normal wear and tear. If this Ground Lease is terminated for any reason or upon the expiration of the Term, the Tenant shall in good faith proceed with (i) any removal of the Facilities and any and all Improvements and (ii) restoration, if any, of the Site to its condition prior to construction of the Facilities and/or Improvements. The Tenant shall have all access rights to the Site that are necessary to remove any and all of the Tenant’s Property, including the Facilities and/or Improvements. The Tenant shall also comply as required by any federal regulations of the Federal Energy Regulatory Commission or any other federal authority with respect to the Facilities on the Site.

7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date the Tenant shall assume full dominion, control and responsibility for the Site, except to the extent specifically provided herein, to the extent provided under LSA - R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real (immovable) or personal (movable) property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its Affiliates and their respective officers, representatives, agents, or employees or the Landlord’s misrepresentations or its breach of or default under this Ground Lease.

 

12


7.3 Holding Over. Except for a Removal Period, if the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, and shall not constitute a renewal or extension of the Term.

8. Use.

8.1 Permitted Uses; Compliance with Laws; Permits. The Tenant may use the Site for any and all uses desired by the Tenant in compliance with all Applicable Laws. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the construction, operation, and maintenance of the Facilities, the Improvements and/or for the Tenant’s use or activities on the Site. The Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Facilities, the Improvements, and the security of the Site, including the timely filing, implementation, and enforcement of any security plan required by Applicable Laws. Any fine or penalty imposed by any Governmental Authority solely caused by the failure of the Tenant to comply with this Section 8.1, including any fine or penalty imposed upon the Landlord as owner of the Site as solely caused by the failure of the Tenant to comply with this Section 8.1, shall be the sole responsibility of the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall indemnify and hold harmless the Landlord from the payment of any such fine or penalty, and the Tenant may pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord.

8.2 Dirt Moving Activities; Permits; Timber.

(a) The Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Site, to the Site, and from portions of the Site to other portions of the Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Site and may do so in its discretion. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Site, including without limitation, for any Improvements, reclamation of lands, erosion control, attainment of spoil, easements/servitudes and/or rights of way; provided, that all costs associated with such efforts shall be the responsibility of the Tenant. Except only as provided in Section 8.2(b), the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Site, and all other rights on and to the Site. Any activities of the Landlord and/or its lessees or assignees or any other party shall not adversely affect the Site or the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any way. Nothing herein is intended to preclude the Landlord, from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation. The Tenant may freely remove any timber which is standing or lying on the Site as the Tenant deems necessary for the Tenant’s intended use of the Site. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights below the surface of the Site.

 

13


(b) To the extent the Landlord holds any rights to oil, gas, or other minerals (“Minerals”) in the Site, the Landlord waives any and all rights of the Landlord or its lessees or assignees to use the surface of the Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the Term, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means consistent with the terms and conditions of this Section 8.3 (b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any way.

8.4 Crossing. The Landlord shall assist the Tenant in the Tenant’s efforts to develop, at the Tenant’s cost, any roads and/or crossings or other Improvements across the Site and boundary lines of the Site to the adjacent land, including relocation of utilities, providing culverts for storm water drainage, and any other Improvements. The Tenant or others, excluding the Landlord, will pay the cost to relocate or modify the infrastructure for these roads and/or crossings and/or other Improvements.

8.3 Access License Agreement. The Landlord hereby consents to the Tenant providing to the Tenant’s Affiliates non-exclusive access to the Site pursuant to one or more access license agreements with its applicable Affiliates; provided that the foregoing shall not serve to modify or limit any of the Landlord’s or the Tenant’s rights and obligations under, or the terms and conditions of, this Ground Lease. Upon Leasehold Lender’s or Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate consenting to such access and related access rights agreements.

8.5 Pipelines; Rights of Way. If at any time the Tenant notifies the Landlord that the Facilities require an off-Site pipeline and/or pipeline servitude for the development, construction or operation of the Facilities at the Site, the Landlord shall, with respect to its own real (immovable) property, grant and, with respect to any other property, use commercially reasonable efforts to cause the applicable landowners and Governmental Authorities to grant, the pertinent approvals to achieve, site, construct and operate and maintain the pipeline and/or pipeline right of way, as directed and on such terms and conditions as reasonably requested by the Tenant.

 

14


9. Indemnification.

9.1 Tenant’s General Agreement to Indemnify. The Tenant releases the Landlord, its officers, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, witness fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Landlord Indemnitee arising out of (i) the use or occupancy of the Site by the Tenant, its officers, representatives, agents, and employees, (ii) the construction or operation of the Facilities by the Tenant, its officers, representatives, agents, and employees, (iii) any claim arising out of the use, occupancy, construction or operation of the Site by the Tenant, its officers, representatives, agents, and employees, and (iv) activities on or about the Site by the Tenant, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, operation, maintenance, or repair of the Site, the Facilities, or the Improvements, by the Tenant, its officers, representatives, agents, and employees; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Landlord Indemnitee shall be excluded from this indemnity. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9.2 and 9.4 and not this Section 9.1.

9.2 Tenant’s Environmental Indemnification. For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with all Environmental Laws applicable to the Tenant, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Tenant agrees to indemnify and hold harmless the Landlord Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorney, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including, without limitation, a Governmental Authority), to the extent arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth above in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Site or any violation of any Environmental Law with respect to the Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, and maintenance activities or facilities and not caused by the Landlord’s Activities or Landlord’s Improvements.

9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Site by the Landlord, its officers, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Site by the Landlord, its officers, representatives, agents, and employees, and (iii) activities on or about the Site by the Landlord, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation,

 

15


damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope but not be limited to any and all claims or actions for wrongful death, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.4 and not this Section 9.3.

9.4 Landlord’s Environmental Indemnification.

(a) For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorneys, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances; (ii) any actual or alleged violation of Environmental Laws, in the case of each of subclauses (i) and (ii), where the presence, discharge or release of such Hazardous Substances or violation of Environmental Law arises or occurs (1) at, on or from the Site on or prior to the Ground Lease Commencement Date or (2) at, on or from the Site or any other site as a result of or relating to the Landlord’s Activities or facilities or Landlord’s Improvements, whether before, on or after the Ground Lease Commencement Date; (iii) the Landlord’s breach of the covenant set forth above in this Section 9.4; or (iv) any environmental condition of contamination on the Site or any violation of any Environmental Law with respect to the Site to the extent occurring after the Ground Lease Commencement Date and caused by the Landlord’s Activities or facilities.

(b) If Hazardous Substances become present or are discharged onto the Site as a result of the Landlord’s Activities or otherwise exist at the Site on or prior to the Ground Lease Commencement Date, the Tenant shall so notify the Landlord in writing as soon as practicable after the Tenant’s discovery thereof. Except with respect to Hazardous Substances that become present or are discharged onto the Site as a result of the Landlord’s Activities, such discovery and notice to the Landlord must occur within the Initial Term of this Ground Lease for the Landlord to have any obligation to perform any Corrective Measures (as hereinafter defined). Except as provided in the following sentence, upon receipt of such notice from the Tenant, the Landlord shall have a reasonable period of time to undertake, at its own expense, but subject to a limit of $5,000,000, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority (“Corrective Measures”), except that such Corrective Measures shall not unreasonably interfere with the construction, operation or maintenance of the Facilities and/or interfere the Improvements by the Tenant. At its discretion, upon written notice to the Landlord, the Tenant shall have the right to undertake such Corrective

 

16


Measures and the Landlord shall reimburse the Tenant up to a total amount of $5,000,000 (or the Tenant may offset against Rent) for its reasonable and necessary documented costs therefor within thirty (30) days after receipt of an invoice by the Landlord (including any costs associated with the work stoppage or interference with the ability of any Facility Contractor to perform its respective obligations under the Facility Contracts (including mobilization and de-mobilization costs, suspension costs, storage costs, rescheduling penalties, and all other direct and indirect costs incurred by the Tenant or any Facility Contractor (and its respective subcontractors) as a result of any delay caused by such Corrective Measures)). The Party not controlling the Corrective Measures under this Section 9.4(b) shall have a reasonable right of participation in the Corrective Measures, including the right to (i) receive copies of material reports, work plans and correspondence relating to the Corrective Measures, (ii) review and comment on draft reports and work plans (and all prompt and reasonable comments shall be considered and addressed by the controlling Party in good faith), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.4(b) shall not supersede or diminish the provisions or the Landlord’s obligations under Section 9.4(a).

9.5 Survival of Indemnities. The foregoing indemnities shall survive the Term and any Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

10. Insurance.

10.1 Tenant Insurance. The Tenant shall carry or cause to be carried commercial general liability insurance with respect to the Site and the uses and activities of the Tenant thereon with minimum limits of [***]. The Tenant may elect to be self-insured in amounts greater than those minimum limits. In the event the Tenant procures commercial general liability insurance, the Landlord will be named as an additional insured.

10.2 Landlord Insurance. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Site and/or any activities of the Landlord with respect to the Site in its reasonable business discretion. The Landlord may elect to be self-insured.

11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. The Landlord shall not create or permit to be created or to remain in connection with the Site, or the Facilities, the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Site or upon the Landlord’s interest in the Site or upon the Tenant’s interest in its leasehold of the Site, in accordance with Section 11.2.

 

17


11.2 Discharge of Liens.

(a) If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

(b) If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such Lien by deposit or by bonding proceedings. Any amount so paid by the non-responsible Party and all costs and expenses incurred by the non-responsible Party in connection therewith, including reasonable attorneys’ fees together with interest thereon at one percent (1%) per annum above the Wall Street Journal Prime Rate of interest published from time to time in the Wall Street Journal, from the respective dates of the non-responsible Party’s making of the payment or incurring of the cost and expense, shall constitute either additional rent payable by the Tenant under this Ground Lease or an offset against Rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Site, including without limitation, any liabilities, obligations and/or debts owed to laborers, vendors, brokers, materialmen, and other service providers, and then offset against the Rent any such amount(s) paid by the Tenant.

12. Entry on Premises by Landlord, Etc.

The Landlord and its representatives shall have no right to enter the Site, except as specifically authorized from time to time in advance in writing by the Tenant after written notice to the Tenant of such request by the Landlord; and such authorization shall be in the Tenant’s sole discretion, and if/when granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of the Tenant. Such entry on the Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions such that access to certain sections of the Site will be restricted.

 

18


13. Destruction by Fire or Other Casualty.

If the Facilities or any Improvements erected on the Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the willful misconduct of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Facilities or the Improvements. In the event that the Tenant so decides not to restore or reconstruct the Facilities or the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove any ruins or rubble remaining on the Site at the Tenant’s sole cost and expense.

14. Assignment; Subleasing; Right of First Refusal.

14.1 Restrictions on Landlord. The Landlord shall not assign this Ground Lease or sell the Site, in whole or in part, (including without limitation by transfer of control or otherwise) without the prior written consent of the Tenant or having complied with Section 14.3. This Ground Lease shall inure to the benefit of and shall be binding upon the Landlord’s permitted assigns.

14.2 Restrictions on Tenant. Subject to the provisions of Section 23, the Tenant shall not assign this Ground Lease, in whole or in part, without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least thirty (30) days prior written notice of any proposed assignment, together with a copy of the proposed assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing, including to a Leasehold Lender, (ii) to a Leasehold Lender or any purchaser upon a foreclosure of a Leasehold Mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a Leasehold Mortgage, (iii) to any Affiliate or member of the Tenant, (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder. The Tenant shall not sublease all or any portion of the Site without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned.

14.3 Right of First Refusal. During the Term, the Landlord may not transfer a portion of the Site and may only transfer the entire Site through a bona fide sale in exchange for a sum certain of money. If the Landlord, during the Term, makes a bona fide offer to sell or receives a bona fide offer from a third party to buy or acquire (individually and collectively a “Bona Fide Offer”) all or any portion of the Site separately or as a part of a larger parcel of which the Site is a part, the Landlord will promptly, within ten (10) Business Days of such making or receipt, give written notice to the Tenant of the terms of the Bona Fide Offer made or received, including the cash price attributable to the Site. If the sale is a tract of which the Site is a part, then the cash price attributable to the Site will be that part of the cash price multiplied times a fraction, the denominator of which is the total number of acres in the Site and the numerator of which is the total number of acres in the larger tract to be sold. The notice shall also state the other terms and conditions of the proposed sale and the Landlord’s willingness to sell for that cash price and on

 

19


those terms. Upon receiving the notice, the Tenant may exercise the right, in the manner specified below, to purchase either the property described in the Bona Fide Offer or the Site (or part thereof) at the lower of: (i) the stated cash price in the Bona Fide Offer or (ii) Fair Market Value, which shall not include any value of this Ground Lease, the Facilities, the Improvements and/or Landlord’s Improvements in the determination of the Fair Market Value, pursuant to the process described in Sections 14.3 through 14.6. This Section 14.3 does not apply to transfers pursuant to successions or donations executed in accordance with Louisiana law.

14.4 Exercise of Right of First Refusal. If the Tenant elects to purchase the property or Site described in the Bona Fide Offer under the provisions of Section 14.3, or if the Tenant elects to seek the Fair Market Value under the provisions of Section 14.3, the Tenant must notify the Landlord of such election, doing so in writing delivered to the Landlord within thirty (30) Business Days after the date of the Landlord’s written notice to the Tenant of the Bona Fide Offer. If the Tenant elects to refuse the Bona Fide Offer, the Tenant need take no action whatsoever; further, if the Tenant fails to deliver to the Landlord a notice of the Tenant’s election within the time required for such notice, the Tenant will be deemed to have refused the Bona Fide Offer. If the Tenant refuses, or is deemed to have refused, the Bona Fide Offer, the Landlord is free to sell the property pursuant to the Bona Fide Offer subject to this Ground Lease, any New Lease, and any Leasehold Mortgage, any Non-Disturbance Agreement and continuation of the leasehold interest created by this Ground Lease and any New Lease.

14.5 Fair Market Valuation. If the Tenant elects to seek the Fair Market Value under the provisions of Section 14.3, then the Tenant shall notify the Landlord of the Tenant’s proposed Fair Market Value for the property or the Site, as the case may be. Thereafter, for a period of thirty (30) days following such notice the Parties shall in good faith attempt to agree upon the Fair Market Value. If the Parties do not agree upon the Fair Market Value within such thirty (30) days, each of the Parties shall within the next thirty (30) days appoint a qualified appraiser to appraise the Fair Market Value (the “First Appraiser” and the “Second Appraiser”) by notice to the other Party. If the Second Appraiser is not timely designated, the determination of the Fair Market Value shall be made solely by the First Appraiser. The First Appraiser, or each of the First Appraiser and the Second Appraiser if the Second Appraiser is timely designated, shall submit its determination of the Fair Market Value to the Parties within thirty (30) days of the date of its selection (or the selection of the Second Appraiser, as applicable). If there are two (2) appraisers and their respective determinations of the Fair Market Value vary by less than ten percent (10%) of the higher determination, the Fair Market Value shall be the average of the two determinations. If such determinations vary by ten percent (10%) or more of the higher determination, the two appraisers shall promptly designate a third appraiser (the “Third Appraiser”). Neither the Tenant nor the Landlord shall provide, and the First Appraiser and Second Appraiser shall be instructed not to provide, any information to the Third Appraiser as to the determinations of the First Appraiser and the Second Appraiser or otherwise influence such Third Appraiser’s determination in any way. The Third Appraiser shall submit its determination of the Fair Market Value to the Parties within thirty (30) days of the date of its selection. The Fair Market Value shall be equal to the average of the two closest of the three determinations. The determination of the Fair Market in accordance with the foregoing procedure shall be final and binding on the Parties. If any appraiser is only able to provide a range in which Fair Market Value would exist, the average of the highest and lowest value in such range shall be deemed to be such appraiser’s determination of the Fair Market Value. Each appraiser selected pursuant to the provisions of this Section 14.5

 

20


shall be a qualified Person with prior experience in appraising industrial lands in south Louisiana and that is not an interested Person with respect to either Party or such Party’s Affiliates. If the Tenant has invoked this process and when the Fair Market Value has been determined, then the Tenant must notify the Landlord in writing within thirty (30) days that the Tenant elects to purchase the property or Site at the lower of either the Fair Market Value determined or the Bona Fide Offer; and if the Tenant fails to notify the Landlord within this thirty (30) day period, then the Landlord is free to sell the property or Site pursuant to the Bona Fide Offer subject to this Ground Lease and any Leasehold Mortgage, any New Lease and any Non-Disturbance Agreement, and continuation of the leasehold interest created by this Ground Lease.

14.6 Continuation of Right. If for any reason the Site is not sold by the Landlord following a Bona Fide Offer from a third-party, the right of first refusal granted and described in the preceding Sections 14.1 through 14.5 shall continue in full force and effect, on the same terms and conditions.

15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of fifteen (15) days after written notice thereof from the Landlord to the Tenant.

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15.1(a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Site or discharge from the Site shall not constitute an Event of Default.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages; Termination. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default, the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the Tenant shall be liable for such reasonable damages unless such Event of Default is reasonably remedied in a timely manner and all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default,

 

21


together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and payable, and all costs and expenses reasonably incurred by or on behalf of the Landlord as a result of the Event of Default, including reasonable attorneys’ fees, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective and is not valid if the Landlord does not give prior written notice to the Tenant pursuant to Section 15.1.

(b) Landlord’s Right to Cure Tenant’s Event of Default. Upon the occurrence of an Event of Default of the Tenant which is not cured or having commenced curing by the Tenant within sixty (60) days as provided in Section 15.2(b), then, subject to the prior written consent of any Leasehold Lender under Section 23, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others to cure the Event of Default. The Tenant shall be responsible for all costs, including attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord.

(c) Sole Recourse. The sole recourse of the Landlord for any damages or liabilities due hereunder shall be limited to the assets of the Tenant, without recourse individually or collectively to the assets of the members or the affiliates of the Tenant, its lenders, or their respective directors, agents, members, shareholders, managers, employees, representatives, partners, and officers.

15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Site to the Landlord, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Site and may have, hold, and enjoy the Site; and (ii) all obligations of the Tenant hereunder for additional rent or any portion thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. In the event of any termination, the Landlord shall be under a duty to seek a successor tenant. If the Landlord obtains a successor tenant during what would have been the remainder of the term of this Ground Lease, the Tenant shall receive a credit for rentals collected from said successor tenant for the remaining Term. If no successor tenant is obtained, the Tenant shall be liable for Rent obligations otherwise provided for in this Ground Lease.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

 

22


16. Events of Default of the Landlord.

16.1 Landlord’s Event of Default; Right to Cure. Any failure of the Landlord to perform and/or to comply with any of its obligations, covenants, agreements, terms, or conditions contained in this Ground Lease shall constitute a “Landlord’s Event of Default” hereunder. The Landlord shall have sixty (60) days after notice by the Tenant to the Landlord of Landlord’s Event of Default to fully cure Landlord’s Event of Default.

16.2 Tenant’s Remedies; Cure. In the event of a Landlord’s Event of Default that is not fully cured under Section 16.1, in addition to all other remedies available to the Tenant, the Tenant may cancel this Ground Lease by written notice to the Landlord. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof, and shall be immediately payable to the Tenant. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default that is not fully cured under Section 16.1.

16.3 Tenant’s Right to Cure Landlord’s Event of Default. Upon the occurrence of a Landlord’s Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord’s Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others, purchasing the required goods or services and procuring necessary insurance. The Landlord shall be responsible for all costs including attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

17. Mutual Obligations.

17.1 Late Charges; Interest. If any Rent or other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of fifteen (15) days after receipt of written notice, such sum shall bear a late charge equal to one percent (1.0%) of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

 

23


17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise (excluding, however, specific performance against the Tenant) and the exercise or beginning of the exercise by the Parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by email or United States registered or certified mail, return receipt and signature requested, postage prepaid, to the Parties at the following numbers and addresses:

 

   To the Tenant:    Venture Global CP2 LNG, LLC   
      1001 19th St North   
      Suite 1500   
      Arlington, VA 22209   
      Attention: [***]   
      Email: [***]   
   With a copy to:    Venture Global CP2 LNG, LLC   
      1001 19th St North   
      Suite 1500   
      Arlington, VA 22209   
      Attention: [***]   
      Counsel Email: [***]   

 

24


   To the Landlord:    [***]   
      28168 Lauderdale Highway   
      Elton, Louisiana 70532   
      [***]   
      P.O. Box 728   
      Cameron, Louisiana 70631   
   With a copy to:    Mudd Bruchhaus & Keating, LLC   
      422 East College Street, Suite B   
      Lake Charles, LA 70605   
      Attn: [***]   

or to such other numbers or addresses as either above designated recipients may from time to time designate by written notice to the other designated recipient hereto at least fifteen (15) days in advance of an effective date stated therein.

18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mail, return receipt and signature requested, postage prepaid.

19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable possession of the Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Site during the Term and any Removal Period without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord. This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow compatible use of the remainder of their property adjacent to the Site and will not create or allow the creation of a visual, olfactory or auditory nuisance on said remainder of their property.

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that: (i) it is the sole owner of good title to all of the Site; (ii) the Site is subject to no Liens, privileges, encumbrances, defects in title, servitudes, easements, restrictions, dedications, leases, mineral leases, reservations or other exceptions to title; (iii) during the Term it shall not encumber the Site; (iv) it is authorized to make this Ground Lease for the Term; (v) the provisions of this Ground Lease do not and will not conflict with or violate any of the provisions of existing agreements between the Landlord and any third party; and (vi) the Landlord will deliver the Site free of all tenants and occupants and claims thereto. The Tenant acknowledges that the Landlord does not have an abstract of title and does not require Landlord to produce one. Tenant will incur the cost of its title review through its professional/attorney selected by Tenant.

 

25


20. Eminent Domain.

20.1 Complete Condemnation. If, during the Term, the whole of the Site shall be taken under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking) by any public or private authority, then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided, that the Tenant shall share in the condemnation award as provided herein. The Tenant may continue to occupy the Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Site from and after the date of such taking.

20.2 Partial Condemnation. If, during the Term, any public or private authority shall under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking), makes a taking resulting in the reduction of the surface area of the Site by fifteen percent (15%) or more, or of fifteen percent (15%) or more of the value of the Facilities, the Improvements or the Landlord’s Improvements, or resulting in material interference to the Tenant’s ability to use in a commercially reasonable manner the remainder of the Site, the Facilities, the Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of the exercise of its election within one-hundred twenty (120) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2, the Term shall cease and this Ground Lease shall terminate as of the last day of the calendar month in which such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant, and the Tenant shall share in the condemnation award as provided herein.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the Term shall continue in full force and effect, and the monthly Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete taking pursuant to Section 20.1, the Tenant will be entitled to receive the portion of the condemnation award (or settlement) attributable to (i) the value of the Facilities, the Improvements, and Landlord’s Improvements, and fixtures and other property located on the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, plus (iii) other compensation or benefits paid as a consequence of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking (if any such compensation or benefits are paid by the applicable taking authority) and the Landlord shall be entitled to recover that portion of the condemnation award (or settlement) fairly attributable to the value of the land taken. In the event Tenant’s Property, the Improvements, or the Facilities are not taken, the Tenant shall not be entitled to any portion of the award. In the event of a partial taking of the Improvements, the Tenant’s Property and/or Facilities, the entire award or settlement shall be paid to the Tenant. In the event of a partial

 

26


taking of the Site, the Tenant will be entitled to receive the portion of the award attributable to (i) the value of the portion of the Facilities, Improvements and Tenant’s Property located in the portion of the Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Site so taken, plus (iii) damage to the remaining Facilities, and the Tenant will promptly restore the remaining portion of the Facilities to the extent of the award payable to the Tenant. Nothing contained herein shall prohibit the Tenant’s claiming relocation damages or damages for lost profits or loss of leasehold advantage against the taking authority in any appropriate proceeding.

21. Temporary Taking or Other Deprivation.

If, during the Term, (i) less than all of the Landlord’s title to all or any portion of the Site is taken for temporary use or occupancy, or (ii) any public or private authority takes any action not resulting in a taking of all or any portion of the Site but resulting in a right to compensation therefor, such as changing of the grade of any street upon which the Site abuts, then, except as otherwise provided in Section 20, the Tenant shall be entitled to make claim for, recover, and retain all awards, whether pursuant to judgment, agreement, or otherwise, recoverable in connection therewith.

22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure; provided, that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section 23 shall govern and control.

23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage, or any agent or trustee therefor, that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant. The term “Leasehold Mortgage” shall mean, at any point in time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as

 

27


the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Site and this Ground Lease. It is acknowledged and agreed that, during the Term, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the Term, the Tenant shall provide the Landlord with written notice of the identity, contact information and address for each Leasehold Lender (or the agent authorized to act on behalf of the Leasehold Lender), such notice to be provided to the Landlord by the Tenant within no less than a calendar year within which the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

23.2 Right to Perform for Tenant; Right to Cure.

(a) In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and the Landlord shall accept such performance by Leasehold Lender with the same force and effect as if furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing.

(b) If any default in the performance of an obligation of the Tenant under this Ground Lease is not susceptible to being cured by Leasehold Lender, the Landlord shall have no right to terminate this Ground Lease with respect to such default and such default shall be deemed waived for the benefit of Leasehold Lender only; provided, that:

(i) Leasehold Lender shall have commenced to cure (i) any other non-payment default of the Tenant that is susceptible to being cured by Leasehold Lender and (ii) any default in the payment of any portion of Rent, in each case, within the time periods prescribed under Section 23.2(a);

(ii) Leasehold Lender (or its designee) shall have commenced to acquire the Tenant’s interest in this Ground Lease and the Site or to commence foreclosure or other appropriate proceedings under the Leasehold Mortgage within the time periods prescribed under Section 23.2(a);

(iii) if Leasehold Lender (or its designee) shall acquire the Tenant’s interest in this Ground Lease and/or the Site, Leasehold Lender (or its designee) shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition; and

 

28


(iv) if any third party shall, by foreclosure or dation en paiement under the Leasehold Mortgage or by assignment or other transfer from Leasehold Lender, acquire the Tenant’s interest in and to the Site under this Ground Lease, such third party shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by a third party with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition.

However, if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then notwithstanding any provision in this Section 23 to the contrary, the Landlord may exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’s prior written consent, and any such action taken without Leasehold Lender’s consent shall not be binding on the Tenant or Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.4 Delivery of Notices. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including, without limitation, any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been delivered to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in writing to the Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

 

29


23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’s interests in the Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including, without limitation, the acquisition of the Tenant’s interest in this Ground Lease and the Site created thereby in a transaction described in this Section 23 or the taking of possession of the Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender; provided, that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Site.

23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2, the purchaser at any sale of this Ground Lease and the interests in and to the Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including, without limitation, power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Site thereby created under any instrument of assignment or transfer in lieu of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Site thereby created.

23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, substantially all, or any part of the Site or the Tenant’s Facilities. Rent shall continue to be due and payable as set forth in this Ground Lease.

23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent

 

30


domain proceeding of all, substantially all, or any part of the Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Facilities, the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Site created by this Ground Lease and the value of the leasehold improvements located on the Site, up to an amount equaling the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Facilities and/or the Tenant’s interest in, under and to this Ground Lease; provided, that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under applicable law to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this Ground Lease. In the event of a taking of a portion of the Site, the Rent shall be reduced pro rata based upon the portion of the Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease.

23.9 New Direct Lease.

(a) If this Ground Lease is canceled or terminated for any reason (except in connection with a Bankruptcy Proceeding, for which the provisions of Section 23.10 are hereby agreed upon by the Landlord and the Tenant), and provided that Leasehold Lender has (i) commenced to cure and continues diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, and (ii) cured any payment default in respect of any portion of Rent, the Landlord hereby agrees that the Landlord shall, upon Leasehold Lender’s written election within one hundred twenty (120) days of such cancellation or termination, promptly enter in a new, direct lease with Leasehold Lender (or its nominee or any other party which Leasehold Lender may designate, including without limitation, the Tenant) with respect to the Site on the same terms and conditions as this Ground Lease (a “New Lease”), it being the intention of the parties to preserve this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Said New Lease shall be superior to all rights, liens and interests intervening between the date of this Ground Lease and the granting of the New Lease and shall be free of any and all rights of the Tenant under this Ground Lease.

(b) The Tenant and the Landlord acknowledge and agree that Leasehold Lender shall have the right to encumber such direct New Lease and the estate created thereby with a deed of trust or a mortgage (as the case may be) on the same terms and with the same lien priority as the Leasehold Mortgage, it being the intention of the parties to preserve the priority of the Leasehold Mortgage, this Ground Lease and the interests in and to the Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. If this Ground Lease is rejected,

 

31


cancelled or terminated for any reason and Leasehold Lender, its nominee or a designee of Leasehold Lender enters into a direct lease with the Landlord with respect to the Site, the Landlord hereby agrees that it will execute such documents as Leasehold Lender may require in order to ensure that the new direct lease provides for customary leasehold mortgagee protections, including without limitation, protections similar to those contained herein.

23.10 Bankruptcy. In the event of a proceeding under the United States Bankruptcy Code (Title 11 U.S.C.) as now or hereafter in effect (a “Bankruptcy Proceeding”):

(a) If this Ground Lease is rejected in connection with a Bankruptcy Proceeding by the Tenant or a trustee in bankruptcy (or other party to such proceeding) for the Tenant, such rejection shall be deemed an assignment by the Tenant to the Leasehold Lender of the Tenant’s Property and all of the Tenant’s interest under this Ground Lease, and this Ground Lease shall not terminate and the Leasehold Lender shall have all rights and obligations of the Tenant as if such Bankruptcy Proceeding had not occurred, unless Leasehold Lender shall reject such deemed assignment by notice in writing to the Landlord within thirty (30) days following rejection of this Ground Lease by the Tenant or the Tenant’s trustee in bankruptcy. If any court of competent jurisdiction shall determine that this Ground Lease shall have been terminated notwithstanding the terms of the preceding sentence as a result of rejection by the Tenant or the trustee in connection with any such proceeding, the rights of Leasehold Lender to a New Lease from the Landlord pursuant to Section 23.9 hereof shall not be affected thereby.

(b) In the event of a Bankruptcy Proceeding against the Landlord:

(i) If the bankruptcy trustee, the Landlord (as debtor-in-possession) or any party to such Bankruptcy Proceeding seeks to reject this Ground Lease pursuant to United States Bankruptcy Code §365(h)(l), the Tenant shall not have the right to treat this Ground Lease as terminated except with the prior written consent of Leasehold Lender and the right to treat this Ground Lease as terminated in such event shall be deemed assigned to Leasehold Lender, whether or not specifically set forth in the Leasehold Mortgage, so that the concurrence in writing of the Tenant and the Leasehold Lender shall be required as a condition to treating this Ground Lease as terminated in connection with such Bankruptcy Proceeding.

(ii) Unless this Ground Lease is treated as terminated in accordance with Section 23.10(b)(i), then this Ground Lease shall continue in effect upon all the terms and conditions set forth herein, including Rent, but excluding requirements that are not then applicable or pertinent to the remainder of the Term. Thereafter, the Tenant or its successors and assigns shall be entitled to any offsets against Rent payable hereunder for any damages arising from such bankruptcy, to the extent the Tenant’s operation of business has been materially interfered with, and any such offset properly made shall not be deemed a default under this Ground Lease. The lien of the Leasehold Mortgage shall extend to the continuing possessory rights of the Tenant following such rejection with the same priority as it would have enjoyed had such rejection not taken place.

 

32


23.11 Estoppel Certificates; Non-Disturbance Agreements.

(a) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel”) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under this Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant thereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that each of this Ground Lease and the Non-Disturbance Agreement, true, correct copies of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, have not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Term is scheduled to expire, (vii) as to the Landlord’s power and authority to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, and any Non-Disturbance Agreement, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which Landlord is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the Landlord Estoppel, the present lessor under this Ground Lease and owns good and indefeasible title to the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (xix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

 

33


(b) Within fifteen (15) days following Leasehold Lender’s or the Landlord’s written request, the Tenant shall provide Leasehold Lender with an estoppel certificate (the “Tenant Estoppel”) which shall certify to such requesting Leasehold Lender (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Landlord of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Landlord of any other conditions required under this Ground Lease, (iii) as to any existing default of the Landlord under this Ground Lease, or alternatively that the Landlord is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Landlord hereunder, and as to any existing event or condition in existence as of the date of the Tenant Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Tenant to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Tenant, (v) that this Ground Lease, a true and correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Term is scheduled to expire, (vii) as to the Tenant’s power and authority to execute the Tenant Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Tenant asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Tenant from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties, or other sums, whether or not constituting rent, due and owing as of the date of the Tenant Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which the Tenant is a party (other than those set forth on a schedule to the Tenant Estoppel), (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Tenant Estoppel, (xiv) that the Tenant is, as of the date of the Tenant Estoppel, the present lessee under this Ground Lease and holds a valid leasehold interest in the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Tenant has not assigned, sublet, hypothecated, leased, or otherwise transferred it interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Tenant’s interest in the Site, other than those set forth on a schedule to the Tenant Estoppel, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Tenant is a party or by which the Tenant is otherwise bound affecting the Tenant’s interest in and to the Site, (xvii) that the Tenant has not commenced any action or sent any notice to the Landlord for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Tenant is not, as of the date of the Tenant Estoppel, entitled to terminate, cancel, modify, or surrender this Ground Lease, and (xviii) as to such other matters related to this Ground Lease as such Leasehold Lender may reasonably determine from time to time.

 

34


(c) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall enter into a non-disturbance agreement with Leasehold Lender or its designee, in the form attached hereto as Exhibit 5 (a “Non-Disturbance Agreement”).

23.12 No Termination by Confusion. There shall be no termination by confusion of this Ground Lease or any interest in this Ground Lease or of the interests in and to the Site created thereby with the fee estate in the Site, by reason of the fact that this Ground Lease or such interest therein, may be directly or indirectly held by or for the account of any person who shall hold any interest in the fee estate in the Site, nor shall there be a merger by reason of the fact that all or any part of the interests in and to the Site created by this Ground Lease may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any interest in the fee estate in the Site or any interest of the Landlord under this Ground Lease.

23.13 Landlord’s Recognition of Tenant. The Landlord hereby recognizes the Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that the Tenant acquired its interest in this Ground Lease and in and to the Site in accordance with the terms of this Ground Lease.

23.14 Agreement to Amend. The Landlord recognizes the importance of the Tenant’s ability to obtain Leasehold Mortgages, and that the provisions of this Ground Lease may be subject to the approval of a Leasehold Lender. If any Leasehold Lender should require, as a condition to such financing, any reasonable modifications of this Ground Lease, whether for purposes of clarifying the provisions of this Ground Lease or to include provisions then customary for leasehold financing transactions, the Landlord agrees to execute the appropriate amendments to this Ground Lease; provided, however, that no such modification shall, to the detriment of the Landlord, impair any of the Landlord’s rights, as reasonably determined by the Landlord or increase any of the Landlord’s obligations, as reasonably determined by the Landlord, under this Ground Lease.

23.15 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

23.16 Subordination of Landlord’s Lien. The Landlord hereby subordinates any lien or privilege it may have on any movables found from time to time in or upon the Site, including without limitation, the Landlord’s privileges pursuant to La. Civil Code articles 2707, et seq., to any Leasehold Lender’s rights under this Section 23 and the lien of any Leasehold Mortgage.

 

35


24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

24.2 Successors. The covenants, agreements, terms, provisions, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties hereto.

24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

24.6 No Oral Change or Termination. This Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties hereto with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, including the Option Agreement, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

 

36


24.9 Litigation. In case of any litigation between the Parties hereto regarding the subject matter hereof, the losing Party shall pay all reasonable costs and expenses (including reasonable attorneys’ fees) of the prevailing Party. The venue of any litigation shall be solely in the 38th Judicial District Court, Cameron Parish.

24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

24.11 Authority. Each of the Landlord and the Tenant represents and warrants that it has the authority to enter into this Ground Lease, that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date, (a) the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 3, evidencing its authority to execute and perform under this Ground Lease and (b) the Landlord shall deliver to the Tenant a resolution in the form attached hereto as Exhibit 4, evidencing its authority to execute and perform under this Ground Lease.

24.12 Brokers and/or Real Estate Agents. Each of the Landlord and the Tenant represents, acknowledges and agrees that it is not represented by any real estate broker/agent and that it is not responsible for payment of any commissions to any real estate brokers/agents in connection with this Ground Lease.

24.13 Legal Relationships; Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. There is no third party beneficiary of this Ground Lease, except as provided in Section 23.15 and any rights of a Leasehold Lender as provided herein. This Ground Lease is the product of the Parties joint negotiation and equal drafting thereof. The language of this Ground Lease shall be construed as a whole according to its fair meaning and not construed strictly for or against any of the Parties pursuant to any statue, case law or rule of interpretation or construction to the contrary.

24.14 Further Assurances. In connection with this Ground Lease and the transactions contemplated hereby, each Party shall execute and deliver any additional documents and instruments and perform any additional acts that may be necessary or appropriate to effectuate and perform the provisions of this Ground Lease and those transactions, including in connection with the requests of any Financing Parties or Leasehold Lender.

24.15 No Waiver or Surrender. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Site and no agreement to accept a surrender of the Site shall be valid unless it is in writing and signed by the Landlord.

 

37


24.16 Memorandum of Lease. The Parties hereto agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’s interest hereunder; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease.

[Remainder of page left intentionally blank; signatures on following pages]

 

38


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

      LANDLORD:
      CARLOTTA ANN SAVOIE

/s/ Jonathan M. Robillard

     
WITNESS Jonathan M. Robillard       By:   

/s/ Carlotta Ann Savoie

/s/ James Savore

        
WITNESS James Savore         

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Calcasieu and State of Louisiana, personally came and appeared Carlotta Ann Savoie, who, after being sworn by me, did execute this agreement on the 12th day of October, 2023 at Lake Charles, State of Louisiana.

  /s/ David P. Bruchaus  

NOTARY PUBLIC

 

1


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

      LANDLORD:
      CHARLOTTE ANNE LABOVE

/s/ Jonathan M Robillard

     
WITNESS Jonathan M Robillard       By:   

/s/ Charlotte Anne LaBove

/s/ Paul A Labone

        
WITNESS Paul A Labone         

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Calcasieu and State of Louisiana, personally came and appeared Charlotte Anne LaBove, who, after being sworn by me, did execute this agreement on the 12th day of October, 2023 at Lake Charles, State of Louisiana.

  /s/ David P. Bruchaus  

NOTARY PUBLIC

 

1


      TENANT:

/s/ Tracy Pelt

      VENTURE GLOBAL CP2 LNG, LLC
WITNESS Tracy Pelt      
      By:   

/s/ Keith Larson

/s/ Jeff Layman

      Name: Keith Larson
WITNESS Jeff Layman       Title:  Secretary

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 6th day of October, 2023 at Arlington, State of Virginia.

  /s/ Michael E. Millan  

NOTARY PUBLIC

 

1


LIST OF EXHIBITS

 

Exhibit 1    Legal Description of the Site
Exhibit 2    Site Survey
Exhibit 3    Tenant’s Resolution
Exhibit 4    Landlord’s Resolution
Exhibit 5    Form of Non-Disturbance Agreement

 

1


EXHIBIT 1

LEGAL DESCRIPTION OF THE SITE

PARCEL “U”

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND ONE HALF INCH DIAMETER IRON PIPE; THENCE S.89°23’14”E., A DISTANCE OF 4,151.02 FEET TO THE NORTHWEST CORNER OF IRREGULAR SECTION 8, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°23’14”E., A DISTANCE OF 915.42 FEET TO THE NORTHWEST CORNER OF IRREGULAR SECTION 9, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°23’14”E., A DISTANCE OF 928.62 FEET TO THE NORTHWEST CORNER OF IRREGULAR SECTION 10, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE & A FOUND TWO INCH DIAMETER IRON PIPE, OFFSET 0.86’ N. 72°16’41”E. OF TRUE POSITION; THENCE S.00°55’56”W., A DISTANCE OF 1,352.76 FEET ALONG THE WEST LINE OF IRREGULAR SECTION 10 TO A POINT BEING MARKED BY A SET ONE QUARTER INCH DIAMETER IRON PIPE OVER A FOUND ONE HALF INCH DIAMETER IRON BAR, SAID POINT BEING THE POINT OF BEGINNING; THENCE S.88°46’08”E., A DISTANCE OF 913.53 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.88°46’08”E., A DISTANCE OF 913.53 FEET TO A POINT ALONG THE EAST LINE OF IRREGULAR SECTION 11, TOWNSHIP 15 SOUTH, RANGE 9 WEST, SAID POINT BEING MARKED BY A FOUND ONE AND ONE, QUARTER INCH DIAMETER IRON PIPE; THENCE S.01°00’56”W. ALONG THE EAST LINE OF IRREGULAR SECTION 11, A DISTANCE OF 2968.01 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.89°03’23”W., A DISTANCE OF 635.71 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE N.89°03’23”W., A DISTANCE OF 573.80 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE N.89°03’23”W., A DISTANCE OF 539.15 FEET TO A POINT BEING MARKED BY A FOUND HALF INCH DIAMETER IRON BAR; THENCE N.89°03’23”W., A DISTANCE OF 74.05 FEET TO A POINT ALONG THE WEST LINE OF IRREGULAR SECTION 10 BEING MARKED BY A FOUND TWO INCH DIAMETER IRON PIPE AND A FOUND HALF INCH DIAMETER IRON BAR, OFFSET 0.39’ S70°18’39”E OF TRUE POSITION; THENCE N.00°55’56”E. ALONG THE WEST LINE OF SAID SECTION, A DISTANCE OF 1,488.58 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°55’56”E. ALONG THE WEST LINE OF SAID SECTION, A DISTANCE OF 1,488.58 FEET TO THE POINT OF BEGINNING. LESS AND EXCEPT 0.9954 ACRES MORE OR LESS DESCRIBED AS PARCEL “V” BELOW.

 

1


SAID DESCRIBED PARCEL, CONTAINING 5,381,227.531 SQUARE FEET OR 123.5360 ACRES, IS SITUATED IN IRREGULAR SECTIONS 10 AND 11, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “U”.

-AND-

PARCEL “V”

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 9, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE & A FOUND TWO INCH DIAMETER IRON PIPE, OFFSET 0.86’ N. 72°16’41”E. OF TRUE POSITION; THENCE S.89°23’17”E., A DISTANCE OF 627.81 FEET ALONG THE NORTH LINE OF SECTION 10, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA; THENCE S.00°55’56” W., A DISTANCE OF 3,471.90 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; SAID POINT BEING THE POINT OF BEGINNING; THENCE S.05°27’00”W., A DISTANCE OF 208.70 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.90°00’00”W, A DISTANCE OF 208.70 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.05°27’00”E., A DISTANCE OF 208.70 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.90°00’00”E, A DISTANCE OF 208.70 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 43,358.79 SQUARE FEET OR 0.9954 ACRES, IS SITUATED IN IRREGULAR SECTION 10, TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “V”.

 

 

FOR PURPOSES OF CLARITY, THE PROPERTY SHALL INCLUDE BOTH PARCEL U AND PARCEL V, COMPRISING APPROXIMATELY 124.5 ACRES.

 

2


EXHIBIT 2

SITE URVEY

[Omitted]


EXHIBIT 3

TENANT’S RESOLUTION

[Omitted]


EXHIBIT 4

LANDLORD’S RESOLUTION

[Omitted]


EXHIBIT 5

FORM OF NON-DISTURBANCE AGREEMENT

[Omitted]

Exhibit 10.61

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

STATE OF LOUISIANA

PARISH OF CAMERON

GROUND LEASE AGREEMENT

(112 Acres)

This GROUND LEASE AGREEMENT (this “Ground Lease”) is executed and effective as of October 24, 2023 (the “Ground Lease Commencement Date”), by and between Venture Global CP2 LNG, LLC, a Delaware limited liability company (the “Tenant”), and Cameron Parish Port, Harbor and Terminal District, acting by and through the Cameron Parish Port Commission, a political subdivision of the State of Louisiana (the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Cameron Parish, Louisiana, consisting of two adjacent parcels on the east bank and west bank, respectively. of the Calcasieu Ship Channel that collectively comprise approximately one hundred twelve (112) acres identified herein as the Site and as further defined below;

WHEREAS, the Tenant is a wholly-owned subsidiary of Venture Global LNG, Inc. (“Venture Global”), which is presently engaged in the business of developing, operating and owning through its subsidiaries projects located in the State of Louisiana concerning liquefied natural gas production and export facilities, terminaling, oil/gas barging operations, berthing, gas liquefaction, regasification and storage, fueling, subleasing and marine construction, maintenance and/or repair and hydrocarbon related industries (each a “VG Project” and, collectively, the “VG Projects”);

WHEREAS, the Tenant wishes to lease land owned by the Landlord for the development, permitting, financing, construction, ownership, operation and/or maintenance of a natural gas liquefaction facility and export terminal of liquefied natural gas (“LNG”), as more fully described in Exhibit 2 (such VG Project, referred to herein as the “Facilities”) and the construction and installation of such other Improvements (as hereinafter defined) on the Site including other ancillary and/or related uses permitted by this Ground Lease; and

WHEREAS, in accordance with the above, the Tenant has executed this Ground Lease and offers fair value to the Landlord as cause and consideration for this Ground Lease.

NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this Ground Lease, and the Parties herein covenant and agree as follows:


1. Definitions and Interpretation.

As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

Adjustment Period” has the meaning set forth in Section 4.1(c).

“Affiliate” means, in respect of any Person, any other Person controlled by, controlling or under common control with such first Person. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of thirty percent (30%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.

Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Site.

Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in the State of New York are authorized or required by law to close.

CLV” means Cameron Land Ventures, LLC, a Delaware limited liability company.

Confidential Information” has the meaning set forth in Section 24.16(a).

Consumer Price Index” has the meaning set forth in Section 4.2.

Corps” has the meaning set forth in Section 8.2(a).

CPI Adjustment” has the meaning set forth in Section 4.1.

CPI Disagreement Notice” has the meaning set forth in Section 4.2.

CPI Notice” has the meaning set forth in Section 4.2.

CPI Percentage Increase” has the meaning set forth in Section 4.2.

Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Law relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

Event of Default” has the meaning set forth in Section 15.1.

 

2


Extended Term” has the meaning set forth in Section 3.2.

Facilities” has the meaning set forth in the Recitals hereof.

Facility Contractor” means any Person (other than the Tenant or its Affiliate) that is party to a Facility Contract.

Facility Contracts” means, collectively, the contracts entered into by the Tenant in connection with the design, engineering, construction, equipment procurement, testing, commissioning, operation and maintenance of the Facilities, the Site and/or the Improvements.

Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Facilities, the Improvements, the Site, or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders.

Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, floods, washouts, explosions; or (ii) weather related events affecting an entire geographic region.

Governmental Approval” means any authorization, waiver, consent, approval, license, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority.

Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

Ground Lease” has the meaning set forth in the Preamble hereof.

Ground Lease Commencement Date” has the meaning set forth in the Preamble hereof.

Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity,

 

3


reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

Hazardous Substances Law” means any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent it relates to the handling of and exposure to hazardous or toxic materials or similar substances.

Improvements” means any and all improvements made by the Tenant, in its sole discretion, to the Site, including marine, rail, and trucking receipt, delivery, and servicing facilities (including piers, marine terminals, bulkheads, wharfs, docks, inlets, wetslips, moonpools, moorings, jetties, and loading and unloading equipment), construction laydown areas, and other utilities and facilities (including berms, open space, security fencing, control rooms, offices, warehouses, parking and yards), in each case, necessary, ancillary, or desirable to the Tenant in connection with the foregoing.

Initial Term” has the meaning set forth in Section 3.1.

Landlord” has the meaning set forth in the Preamble hereof.

Landlord Estoppel” has the meaning set forth in Section 23.9(a).

Landlord Indemnitee” has the meaning set forth in Section 9.1.

Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, commissioners, members, invitees, agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Site and/or Landlord’s Improvements.

 

4


Landlord’s Event of Default” has the meaning set forth in Section 16.1.

Landlord’s Improvements” has the meaning set forth in Section 6.1.

Lease Year” means a period of twelve (12) consecutive full calendar months. The first Lease Year shall begin on the Ground Lease Commencement Date. Each succeeding Lease Year shall commence upon the anniversary of the first day of the previous Lease Year.

Leasehold Lenders” has the meaning set forth in Section 23.1.

Leasehold Loan” has the meaning set forth in Section 23.1.

Leasehold Mortgage” has the meaning set forth in Section 23.1.

Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

Minerals” has the meaning set forth in Section 8.3(b).

Option Agreement” means the Real Estate Lease Option Agreement between Landlord and Tenant (as successor in interest to CLV), dated as of June 1, 2021.

Party” or “Parties” has the meaning set forth in the Preamble hereof.

Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

Property Taxes” means all real (immovable) and personal (movable) property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

Removal Period” means the period of time that is required by Tenant to remove any and all of Tenant’s Property, including the Facilities and/or Improvements, from the Site in accordance with Section 7.1.

Rent” has the meaning set forth in Section 4.1.

Shipping Fee” has the meaning set forth in Section 4.3.

 

5


Site” means the real (immovable) property of approximately one hundred twelve (112) acres described in the legal description set forth in Exhibit 1-A, and illustrated by the Survey Map attached as Exhibit 1-B, upon certain portions of which the Facilities and any Improvements will be located and which real (immovable) property is owned by the Landlord, and excluding, for the avoidance of doubt, the Submerged Area.

Stipulated Acreage” has the meaning set forth in Section 2.2.

Submerged Area” means the portion of Section 32 in Cameron Parish, Louisiana that is presently submerged by the Calcasieu Ship Channel, as depicted by the Survey Map.

Surface Waiver” has the meaning set forth in Section 8.2(b).

Survey Map” means the ALTA survey of the Site, dated May 14, 2020, by Lonnie G. Harper & Associates, Inc., attached as Exhibit 1-B.

Tenant” has the meaning set forth in the Preamble hereof.

Tenant Estoppel” has the meaning set forth in Section 23.9(b).

Tenant Indemnitee” has the meaning set forth in Section 9.3.

Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Site by or on behalf of the Tenant, including the Facilities and any Improvements.

Venture Global” has the meaning set forth in the Recitals hereof.

VG Project” has the meaning set forth in the Recitals hereof.

Western Parcel” means that certain tract of land in Section 32 on the west bank of the Calcasieu Ship Channel in Cameron Parish, Louisiana, consisting of approximately seventy-four (74) acres, forming part of the Site.

1.2 Interpretation. Unless the context otherwise requires:

(a) Words singular and plural in number will be deemed to include the other and pronouns having a masculine or feminine gender will be deemed to include the other;

(b) Any reference to this Ground Lease or any other contract or agreement in respect of the Site means such agreement and all schedules, exhibits and attachments thereto as may be amended, supplemented or otherwise modified and in effect from time to time, and shall include a reference to any document which amends, modifies or supplements it, or is entered into, made or given pursuant to or in accordance with its terms;

 

6


(c) The terms “hereof,” “herein,” “hereby,” “hereto” and similar words refer to this entire Agreement and not any particular Section, subsection or other subdivision of, or Exhibit, appendix or schedule to, this Ground Lease;

(d) The terms “include” and “including” shall be construed as being at all times followed by the words “without limitation” or “but not limited to” unless the context specifically indicates otherwise;

(e) References to “Article,” “Section” or “Exhibit” are to this Ground Lease unless specified otherwise;

(f) References to any law, statute, rule, regulation, notification or statutory provision (including Applicable Laws) shall be construed as a reference to the same as it may have been, or may from time to time be, amended, modified or re-enacted;

(g) References to any Person shall be construed as a reference to such Person’s successors, heirs and permitted assigns; and

(h) The word “or” will have the inclusive meaning represented by the phrase “and/or”.

2. Ground Lease Premises.

2.1 Date. The date of this Ground Lease is the Ground Lease Commencement Date.

2.2 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of the rents and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does lease to the Tenant and the Tenant hereby leases from the Landlord, the one hundred twelve (112) acre Site and Landlord’s Improvements; provided that, solely for the purposes of calculating the compensation payable by the Tenant to the Landlord set forth in Section 4.1, the Site is deemed to comprise exactly one hundred twenty (120) acres (the “Stipulated Acreage”).

2.3 Servitudes. In addition, the Landlord shall without cost to the Tenant, grant from time to time to the Tenant and others designated by the Tenant (including any Affiliate of the Tenant) any servitudes and rights of way for access and electricity, communications, dredging, gas, water, sewer and other utility lines, products and materials from and to the Site over land and waterways owned by the Landlord and sufficient to permit the Tenant to accomplish its purposes in connection with the Improvements and the Facilities.

2.4 Coast Guard Property. In addition, the Landlord shall use reasonable efforts to obtain fee ownership of that certain parcel located within the Site that is presently owned by the United States Coast Guard (as depicted on Exhibit 1-B), together with a release or quitclaim of all rights, claims and interests of the United States Coast Guard to such parcel, no later than 180 days following the Ground Lease Commencement Date and, upon the Tenant’s reasonable request, provide updates to the Tenant relating to such efforts. Until such time as the foregoing ownership and release are obtained, references herein to the “Site” shall be deemed to exclude such parcel.

 

7


3. Term

3.1 Initial Term. The initial term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on the thirtieth (30th) anniversary of the Ground Lease Commencement Date (the “Initial Term”).

3.2 Extensions.

(a) In consideration of and conditioned upon there being no uncured Event of Default on the part of the Tenant at the time an option is exercised, the Landlord hereby grants unto the Tenant the option to lease the Site for four (4) additional ten (10) year terms. If the extension option is exercised in accordance with Section 3.2(b). the first of said additional terms shall commence upon the expiration of the Initial Term and extend for a period of ten (10) years and each of said additional terms shall commence upon the expiration of the then-current additional term and extend for a period of ten (10) years. Each of such additional terms is referred to herein as an “Extended Term” and, collectively, the Initial Term and any Extended Terms are referred to herein as the “Term”.

(b) The option to extend this Ground Lease of the Site as set forth in Section 3.2(a) must be exercised in each case, if at all, by written notice from the Tenant to the Landlord on or before the date that is three (3) months prior to the expiration of the Initial Term or the then-current Extended Term, as applicable. The failure of the Tenant to timely exercise the first Extended Term or any subsequent Extended Term shall automatically terminate the right of the Tenant to exercise its option to lease the Site in any subsequent Extended Term.

(c) All the terms and conditions of this Ground Lease shall be applicable to any Extended Term and the Rent payable by the Tenant for any Extended Term shall be in accordance with the provisions set forth in Article 4.

(d) The Tenant may not exercise its right to extend the term of this Ground Lease if an Event of Default with respect to the Tenant has occurred and continued uncured for sixty (60) consecutive days.

4. Compensation

4.1 Rent. Commencing upon the Ground Lease Commencement Date, the initial rent for the Site (“Rent”) shall be equal to the product of [***], per month, adjusted upward every five (5) years thereafter during the Term by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment during any Adjustment Period (as defined below) of greater than [***]. The period of time from the Ground Lease Commencement Date through the date five years thereafter, and each five (5) year period thereafter shall be defined herein as an

 

8


Adjustment Period.” Any upward adjustment based on a CPI Percentage Increase (as defined below) to any payment under this Ground Lease shall hereinafter be referred to as a “CPI Adjustment.” Such Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month; provided, however, that: (x) the first payment of Rent shall be due on the Ground Lease Commencement Date (less any credit contemplated under Section 2.C of the Option Agreement) and, if the Ground Lease Commencement Date is a date other than the first day of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; (y) the first payment of Rent due upon the commencement of any new Adjustment Period will be owed and paid one month after the commencement of that Adjustment Period in order to permit the Tenant to calculate the CPI Percentage Increase, as set forth below; and (z) the last payment of Rent shall be in a prorated amount for the period of time between the immediately preceding first day of the month and the last day of the Term.

4.2 CPI Adjustment. If the CPI Percentage Increase (as defined below) is more than [***] for the relevant Adjustment Period, then the Rent payable during that Adjustment Period shall be adjusted upward by a percentage equal to the CPI Percentage Increase (as defined below) applicable to such Adjustment Period, but not to exceed an adjustment during any Adjustment Period of greater than [***]. The term “Consumer Price Index” shall mean the unadjusted Consumer Price Index for All Urban Workers, U.S. City Average, All Items, 1982-84= 100, calculated and published by the United States Department of Labor, Bureau of Labor Statistics. The “CPI Percentage Increase” shall mean, with respect to any Adjustment Period, [***]. For the avoidance of doubt, no CPI Adjustment shall be made to any payment due under this Ground Lease for any Adjustment Period if the result of such CPI Adjustment would be to (a) reduce the amount of such payment to an amount that is less than [***] greater than the amount of such payment due for the immediately preceding Adjustment Period or (b) to raise the amount of such payment to an amount that is greater than [***]. For illustrative purposes only, [***]. The CPI Percentage Increase for any Adjustment Period shall be calculated by the Tenant, and the Tenant shall deliver written notice to the Landlord describing such calculation in reasonable detail (a “CPI Notice”) no later than thirty (30) days after the commencement of any Adjustment Period. If the Landlord disagrees with the Tenant’s calculation of the CPI Percentage Increase, then the Landlord shall deliver to the Tenant written notice, describing the basis for such disagreement in reasonable detail (a “CPI Disagreement Notice”), not later than thirty (30) days after delivery of the CPI Notice. If the Landlord fails to deliver a CPI Disagreement Notice within thirty (30) days after delivery of any CPI Notice, then the Landlord shall be conclusively deemed to have agreed with the calculation of the CPI Percentage Increase set forth in such CPI Notice.

 

9


4.3 Shipping Fees. [***].

4.4 Business Days. If the day on which any amount hereunder is due and payable is not a Business Day, such amount shall not be due and payable until the next following Business Day.

4.5 Place of Payment. Except as otherwise provided herein, Rent shall be payable by check or wire transfer at the following address or via wire instructions provided by the Landlord to the Tenant in writing, or to such other place as the Landlord may specify and the Tenant deem acceptable.

5. Net Lease; Taxes and Utility Expenses.

5.1 Net Lease. This Ground Lease is a net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs, if any, of every kind and nature whatsoever relating to the Site except as expressly otherwise provided in this Ground Lease.

5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and Governmental Approval fees applicable to the Site during the Term.

 

10


(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on or related to the Improvements and the underlying real property comprising the Site, subject to Section 5.2(c), during the Term (prorated on the basis of a 365-day year to account for any fractional portion of a fiscal tax year included in at the commencement or expiration of the Term). The Landlord shall promptly provide all Property Tax bills to the Tenant when they become available. Upon the latter of (i) one (1) month after receipt of such Property Tax bill from the Cameron Parish Tax Collector Landlord or (ii) the due date of any such Property Taxes, the Tenant shall provide the Landlord with reasonable written evidence from the Cameron Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided, that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

(c) The Landlord shall provide written notice to the Tenant of its receipt of any oral or written notice of any audit, examination, claim or assessment relating to Property Taxes on or related to the Improvements within ten (10) Business Days following receipt of such notice. The Tenant may, or if, required by Applicable Law, the Landlord shall at the Tenant’s election and in compliance with the Tenant’s direction, initiate a claim and commence proceedings with the appropriate Governmental Authority to contest, resolve, appeal, defend and settle any such audit, examination, claim or assessment, as applicable, relating to Property Taxes, and in, any event, the Landlord shall fully cooperate with the Tenant with respect to any such claim or proceeding. The Landlord and the Tenant shall otherwise reasonably coordinate to properly and timely remit Property Taxes assessed and owed, including through coordination with the Cameron Parish Tax Collector’s Office, the Cameron Parish Tax Assessor’s Office and any other relevant Governmental Authorities.

5.3 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost, electricity, telephone, water, sewerage, gas, and other utility services to the Site.

6. Tenant and Landlord Improvements.

6.1 Landlord’s Improvements.Landlord’s Improvements” are any and all improvements to the immovable property of the Site and any and all movable property in existence on the Site at the time of the Ground Lease Commencement Date. There are no Landlord’s Improvements on the Site as of the Ground Lease Commencement Date.

6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install on the Site, any Improvements during the Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. During the Term, the Tenant shall be permitted to make any changes, improvements or alterations to the Site, including, without limitation, the Facilities, the Landlord’s Improvements and any Improvements to the Site, as long as the changes, alterations and/or Improvements comply with Applicable Laws.

 

11


6.3 Governmental Approvals. The Tenant shall be responsible for obtaining any and all Governmental Approvals deemed necessary by the Tenant for the Facilities and all other Improvements to the Site, including with respect to Governmental Approvals from the Federal Energy Regulatory Commission and the Department of Energy. The Landlord will hereafter continue to be obligated to execute appropriate documentation to waive its right to require wetlands mitigation to be completed on the Site or other real (immovable) property owned by the Landlord, in such form as necessary to allow the Tenant to complete such wetlands mitigation at locations other than other real (immovable) property owned by the Landlord.

6.4 Tenant’s Property. Tenant’s Property shall at all times be and remain the sole property of the Tenant.

6.5 Maintenance of Improvements.

(a) Tenant’s Obligation to Maintain. During the Initial Term or any Extended Term, as applicable, the Tenant will keep in reasonably good state of repair the Facilities, the Improvements, open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Site by the Tenant, and the Tenant will, in its sole discretion and cost, repair such property as often as may be necessary in order to keep the Facilities and the Improvements in reasonably good repair and condition, except as set forth in Section 6.5(b).

(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease, the Landlord has no obligation to maintain the Site, Improvements and/or Landlord’s Improvements (if any) during the Term. The Landlord further agrees that there will be no Landlord improvements on the Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

7. Tenant’s Surrender of Site.

7.1 Surrender at End of Ground Lease. Subject to Section 6.4, the Tenant shall and will on the last day of the Initial Term, or if extended, on the last day of the Extended Term hereof, surrender and deliver the Site to the Landlord, in the condition of the Site as of the Ground Lease Commencement Date, excepting normal wear and tear. If this Ground Lease is terminated for any reason or upon the expiration of the Initial Term and/or Extended Term (if extended) of this Ground Lease, the Landlord may elect (a) to retain all or any portion of the Facilities and Improvements on the Site, including docking material, bulkhead and buildings, or (b) to require the Tenant to remove all or any portion of the Facilities and Improvements and otherwise restore the Site as set forth in the first sentence of this Section 7.1, including any areas of the Site excavated by the Tenant during the Term. The Tenant shall have all access rights to the Site that are necessary to remove any or all of the Tenant’s Property, including the Facilities and/or Improvements. The Tenant shall provide such reasonable cooperation and information as requested by the Landlord with respect to the restoration of any excavated portion of the Site and the preservation of the Landlord’s ownership rights thereto. The Tenant shall also comply as required by any federal regulations of the Federal Energy Regulatory Commission or any other federal authority with respect to the Facilities on the Site.

 

12


7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date the Tenant shall assume full dominion, control and responsibility for the Site, except to the extent specifically provided herein, to the extent provided under LSA – R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real (immovable) or personal (movable) property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its members, commissioners, representatives, agents, or employees or the Landlord’s misrepresentations or its breach of or default under this Ground Lease.

7.3 Holding Over. Except for a Removal Period, if the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, and shall not constitute a renewal or extension of the Term.

8. Use.

8.1 Permitted Uses; Compliance with Laws; Permits. The Tenant may use the Site for any and all uses desired by the Tenant in compliance with all Applicable Laws. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the construction, operation, and maintenance of the Facilities, the Improvements and/or for the Tenant’s use or activities on the Site. The Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Facilities, the Improvements, and the security of the Site, including the timely filing, implementation, and enforcement of any security plan required by Applicable Laws. Any fine or penalty imposed by any Governmental Authority caused in whole or in part by the failure of the Tenant to comply with this Section 8.1, including any fine or penalty imposed upon the Landlord as owner of the Site and caused in whole or in part by the failure of the Tenant to comply with this Section 8.1, shall be the sole responsibility of the Tenant to the extent so caused by the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall indemnify and hold harmless the Landlord from the payment of any such fine or penalty, and the Tenant shall pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord.

8.2 Dirt Moving Activities; Permits; Timber.

(a) Without limiting the Tenant’s restoration obligations set forth in Section 7.1, the Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Site, to the Site, and from portions of the Site to other portions of the Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Site and may do so in its discretion. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Site, including without limitation, for any Improvements,

 

13


reclamation of lands, erosion control, attainment of spoil, easements/servitudes and/or rights of way; provided, that all costs associated with such efforts shall be the responsibility of the Tenant. Except only as provided in Section 8.2(b), the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Site, and all other rights on and to the Site. Any activities of the Landlord and/or its lessees or assignees or any other party shall not adversely affect the Site or the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any way. Nothing herein is intended to preclude the Landlord, from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation. The Tenant may freely remove any timber which is standing or lying on the Site as the Tenant deems necessary for the Tenant’s intended use of the Site. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights below the surface of the Site.

(b) To the extent the Landlord holds any rights to oil, gas, or other minerals (“Minerals”) in the Site, the Landlord waives any and all rights of the Landlord or its lessees or assignees to use the surface of the Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the Term, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means consistent with the terms and conditions of this Section 8.2(b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Facilities or interfere with the Tenant’s operations or rights under this Ground Lease in any way.

(c) To the extent of the Landlord’s rights with respect to all or any portion of the Submerged Area, the Landlord agrees not to exercise any such rights or otherwise make use of such Submerged Area without the Tenant’s prior written consent. Nothing in this Section 8.2(c) shall be construed to limit the Landlord’s right to use the Calcasieu Ship Channel waterway.

8.3 Access License Agreement. The Landlord hereby consents to the Tenant providing to the Tenant’s Affiliates non-exclusive access to the Site pursuant to one or more access license agreements with its applicable Affiliates; provided that the foregoing shall not serve to modify or limit any of the Landlord’s or the Tenant’s rights and obligations under, or the terms and conditions of, this Ground Lease. Upon Leasehold Lender’s or Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate consenting to such access and related access rights agreements.

8.4 Pipelines; Rights of Way. If at any time the Tenant notifies the Landlord that the Facilities require an off-Site pipeline and/or pipeline servitude for the development, construction or operation of the Facilities at the Site, the Landlord shall, with respect to its own real (immovable) property, grant the pertinent approvals to achieve, site, construct and operate and maintain the pipeline and/or pipeline right of way, as directed and on such terms and conditions as reasonably requested by the Tenant.

 

14


9. Indemnification.

9.1 Tenant’s General Agreement to Indemnify. The Tenant releases the Landlord, its members, commissioners, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to defend, indemnity and hold harmless the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses imposed on, incurred by or asserted against any Landlord Indemnitee arising out of (i) the use or occupancy of the Site by the Tenant, its officers, representatives, agents, and employees, (ii) the construction or operation of the Facilities by the Tenant, its officers, representatives, agents, and employees, (iii) any claim arising out of the use, occupancy, construction or operation of the Site by the Tenant, its officers, representatives, agents, and employees, and (iv) activities on or about the Site by the Tenant, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, operation, maintenance, or repair of the Site, the Facilities, or the Improvements, by the Tenant, its officers, representatives, agents, and employees; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Landlord Indemnitee shall be excluded from this indemnity. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9.2 and 9.4 and not this Section 9.1.

9.2 Tenant’s Environmental Indemnification. For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with all Environmental Laws applicable to the Tenant, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Tenant agrees to defend, indemnify and hold harmless the Landlord Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses, which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including, without limitation, a Governmental Authority), to the extent arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth above in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Site or any violation of any Environmental Law with respect to the Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, and maintenance activities or facilities and not caused by the Landlord’s Activities or Landlord’s Improvements.

9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to defend, indemnify, and hold harmless the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses, imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Site by the Landlord, its members, commissioners, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Site by the Landlord, its members, commissioners, representatives,

 

15


agents, and employees, and (iii) activities on or about the Site by the Landlord, its members, commissioners, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation, damage or penalty to the extent arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope but not be limited to any and all claims or actions for wrongful death, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.4 and not this Section 9.3.

9.4 Landlord’s Environmental Indemnification. For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Site. The Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances, but only to the extent caused by the Landlord or any of Landlord’s prior tenants; (ii) any actual or alleged violation by the Landlord of Environmental Laws; or (iii) the Landlord’s breach of the covenant set forth above in this Section 9.4. The Landlord represents and warrants to the Tenant that neither the Landlord no any prior tenant of the Landlord has, on or prior to the Ground Lease Commencement Date, conducted any activities or operations on the Site.

9.5 Survival of Indemnities. The foregoing indemnities shall survive the Initial Term, any Extended Term and any Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

10. Insurance.

10.1 Tenant Insurance. The Tenant shall carry or cause to be carried commercial general liability insurance with respect to the Site and the uses and activities of the Tenant thereon with minimum limits of [***]. The Tenant may elect to be self-insured in amounts greater than those minimum limits. In the event the Tenant procures commercial general liability insurance, the Landlord will be named as an additional insured.

10.2 Landlord Insurance. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Site and/or any activities of the Landlord with respect to the Site in its reasonable business discretion. The Landlord may elect to be self-insured.

 

16


11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. The Landlord shall not create or permit to be created or to remain in connection with the Site, or the Facilities, the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Site or upon the Landlord’s interest in the Site or upon the Tenant’s interest in its leasehold of the Site, in accordance with Section 11.2.

11.2 Discharge of Liens.

(a) If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Site or any part thereof in connection with the Facilities, the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

(b) If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such Lien by deposit or by bonding proceedings. Any amount so paid by the non-responsible Party and interest thereon at judicial rate of interest under the Applicable Laws of the State of Louisiana from the respective dates of the non-responsible Party’s making of the payment or incurring of the cost and expense, shall constitute either additional rent payable by the Tenant under this Ground Lease or an offset against Rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Site, including without limitation, any liabilities, obligations and/or debts owed to laborers, vendors, brokers, materialmen, and other service providers, and then offset against the Rent any such amount(s) paid by the Tenant.

12. Entry on Premises by Landlord, Etc.

The Landlord and its representatives shall have the right to access and observe the Site during business hours and upon reasonable prior notice to the Tenant; provided, however, that during such time as the Site is under development or construction, such right to access and observation shall be subject to the Tenant’s reasonable discretion and any limitations or requirements of Applicable

 

17


Law and Governmental Approvals and the safety protocols of Facility Contractors and others present on the Site. If and when access is granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of the Tenant. Such entry on the Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions such that access to certain sections of the Site will be restricted.

13. Destruction by Fire or Other Casualty.

If the Facilities or any Improvements erected on the Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the negligence, willful misconduct, or other fault of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Facilities or the Improvements. In the event that the Tenant so decides not to restore or reconstruct the Facilities or the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove any ruins or rubble remaining on the Site at the Tenant’s sole cost and expense.

14. Assignment; Subleasing.

14.1 Restrictions on Landlord. The Landlord shall not sell the Site, in whole or in part, directly or indirectly (including without limitation by transfer of control or otherwise) without the prior written consent of the Tenant; provided, however, that such written consent of the Tenant shall not be so required if an Event of Default described in Section 15.1(a) has occurred and is then continuing. This Ground Lease shall inure to the benefit of and shall be binding upon the Landlord’s permitted assigns and/or vendees.

14.2 Restrictions on Tenant. The Tenant represents that it has been formed to pursue a VG Project and for no other purpose. Subject to the provisions of Section 23, the Tenant shall not assign or sublease this Ground Lease, in whole or in part, without the prior written consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least thirty (30) days prior written notice of any proposed assignment, together with a copy of the proposed assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing (ii) to any purchaser upon a foreclosure of a mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a mortgage, (iii) to any Affiliate or member of the Tenant, (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder. The Tenant shall not sublease all or any portion of the Site without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed or conditioned. It is expressly understood and agreed by and between Tenant and Landlord that (i) it shall be reasonable

 

18


for the Landlord to withhold its consent to any sublease of all or any portion of the Site to any tenant that (x) is seeking such sublease in order to terminate an existing lease with the Landlord or any other landowner in Cameron Parish in respect of other real property (immovable property) or (y) in the case of the portion of the Site located on Monkey Island, intends to use the Site to service, or moor rigs engaged in or designated for, oil and gas drilling and production operations in the Gulf of Mexico (unless authorized by the Landlord) and (ii) Landlord consents to the sublease by Tenant of the Western Parcel, subject to the restrictions set forth in clause (i)(x) and the following two sentences (which restrictions shall be included in any such sublease), to CLV. Further, Tenant agrees that it shall not sublease, under any circumstance whatsoever, to Lake Charles Pilots, Inc. or any Affiliate, subsidiary, parent or other company providing the same or similar services. Likewise, Tenant agrees not to sublease the Site to any company providing tug service to the LNG vessels. Any assignment or sublease by Tenant, however, shall be upon the express qualification that, without Owner’s express agreement to the contrary, such assignment or sublease, shall not be deemed to modify any of the terms of this Agreement or to relieve the Tenant from any of its obligations hereunder, and Landlord may continue to look to the initial Tenant alone for the payment of all sums due hereunder and the fulfillment of all covenants on the part of Tenant hereunder, with the same force and effect as if such assignment or sublease had not been executed.

15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of fifteen (15) days after written notice thereof from the Landlord to the Tenant.

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15.1(a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Site or discharge from the Site shall not constitute an Event of Default.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages. Upon the occurrence of an Event of Default, the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the Tenant shall be liable for such

 

19


reasonable damages unless such Event of Default is reasonably remedied in a timely manner and all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default, together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and payable, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective unless notice is given within 15 days of the date when the Landlord obtains actual knowledge of the Event of Default.

(b) Termination. Upon the occurrence of an Event of Default described in Section 15.1(a) and following such sixty (60)-day cure period described in Section 15.2(a), unless the Landlord agrees to an extended cure period thereof, the Landlord may terminate this Ground Lease by written notice to the Tenant and pursue remedies at law or in equity, including the right to specific performance, with or without termination of this Ground Lease.

(c) Landlord’s Right to Cure Tenant’s Event of Default. Upon the occurrence of an Event of Default described in Section 15.1(b) and following such sixty (60)-day cure period described in Section 15.2(a), unless the Landlord agrees to extend such cure period, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default. The Tenant shall be responsible for all costs, excluding any attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord. Rent shall still be due and payable during the time granted to cure an Event of Default.

15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Site to the Landlord, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Site and may have, hold, and enjoy the Site; and (ii) all obligations of the Tenant hereunder for additional rent or any portion thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

 

20


16. Events of Default of the Landlord.

16.1 Landlord’s Event of Default; Right to Cure. Any failure of the Landlord to perform and/or to comply with any of its obligations, covenants, agreements, terms, or conditions contained in this Ground Lease shall constitute a “Landlord’s Event of Default” hereunder. The Landlord shall have sixty (60) days after notice by the Tenant to the Landlord of Landlord’s Event of Default to fully cure Landlord’s Event of Default.

16.2 Tenant’s Remedies; Cure. In the event of a Landlord’s Event of Default that is not fully cured under Section 16.1, in addition to all other remedies available to the Tenant, the Tenant may cancel this Ground Lease by written notice to the Landlord. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof, and shall be immediately payable to the Tenant. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default that is not fully cured under Section 16.1.

16.3 Tenant’s Right to Cure Landlord’s Event of Default. Upon the occurrence of a Landlord’s Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord’s Event of Default. The Landlord shall be responsible for all costs, excluding attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

17. Mutual Obligations

17.1 Late Charges; Interest. If any Rent or other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of fifteen (15) days after receipt of written notice, such sum shall bear a late charge equal to one percent (1.0%) of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall

 

21


be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise and the exercise or beginning of the exercise by the Parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by email or United States registered or certified mail, return receipt and signature requested, postage prepaid, to the Parties at the following numbers and addresses:

 

To the Tenant:   

Venture Global CP2 LNG, LLC

1001 19th St North

Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer

Email: [***]

With a copy to:   

Venture Global CP2 LNG, LLC

1001 19th St North

Suite 1500

Arlington, VA 22209

Attention: General Counsel

Email: [***]

To the Landlord:   

Port Commissioners

The Cameron Parish Port, Harbor and Terminal

District

180 Henry Street

Cameron, LA 70631

Email: [***]

or to such other numbers or addresses as either above designated recipients may from time to time designate by written notice to the other designated recipient hereto at least fifteen (15) days in advance of an effective date stated therein.

 

22


18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mail, return receipt and signature requested, postage prepaid.

19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable possession of the Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Site during the Initial Term, any Extended Term and any Removal Period of this Ground Lease without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord. This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow compatible use of the remainder of their property adjacent to the Site and will not create or allow the creation of a visual, olfactory or auditory nuisance on said remainder of their property.

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that it is the sole owner of good title to all of the Site and that during the term hereof it shall not encumber the Site.

20. Eminent Domain.

20.1 Complete Condemnation. If, during the term hereof, the whole of the Site shall be taken by a Governmental Authority under the power of eminent domain (or the Site is sold in lieu of a taking under threat of exercise of the power of eminent domain by a Governmental Authority or entity authorized to exercise such power, condemnation or taking), then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided, that each Party may claim for a condemnation award in accordance with Section 20.4 and all Applicable Laws. Tenant may continue to occupy the Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, shall be refunded to the Tenant. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Site from and after the date of such taking.

20.2 Partial Condemnation. If, during the term hereof, any Governmental Authority shall, under the power of eminent domain (or a portion of the Property is sold in lieu of a taking under threat of the use of such power) makes a taking resulting in the reduction of the surface area of the Site by fifteen percent (15%) or more, or of fifteen percent (15%) or more of the value of the Facilities, the Improvements or the Landlord’s Improvements, or resulting in material interference to the Tenant’s ability to use in a commercially reasonable manner the remainder of the Site, the Facilities, the Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of the exercise of its election within one-hundred twenty (120) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2,

 

23


the term hereof shall cease and terminate thirty (30) days from the date such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant for the period of time that is after the later of the termination date as determined above or the date Tenant actually ceases to occupy the Site, with said refund to be paid within thirty (30) days from the said date, and each Party may claim for a condemnation award in accordance with Section 20.4 and all Applicable Laws.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the term hereof shall continue in full force and effect, and the monthly Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete, partial or temporary taking, condemnation or other action, or threat of action, by a Governmental Authority resulting in termination of this Ground Lease and a right to compensation pursuant to Section 20.1 or Section 20.2, (a) the Tenant shall be entitled to claim from applicable Governmental Authorities in appropriate proceedings a condemnation award (or settlement) attributable to, as applicable, (i) the value of the Facilities, the Improvements, and Tenant’s fixtures and other property located on the Site so taken, plus (ii) without duplication with clause (i) above, the value of the Tenant’s leasehold estate in the Site under this Ground Lease, plus (iii) other compensation or benefits paid as a consequence of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking, including relocation damages or damages for lost profits or loss of leasehold advantage and (b) the Landlord shall be entitled to claim from applicable Governmental Authorities in appropriate proceedings a condemnation award (or settlement) fairly attributable to, as applicable, the value of the Site, the value of any Landlord’s Improvements and unpaid rents which would have been due to the Landlord under this Ground Lease after the date of the taking or sale under threat of eminent domain. The amounts described in each of the foregoing clauses (a) and (b) shall be separate and mutually exclusive, and neither Party shall dispute or otherwise interfere with a claim made by the other Party in accordance with Applicable Laws pursuant to the foregoing.

21. Reserved.

22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure; provided, that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

 

24


23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section shall govern and control.

23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage, or any agent or trustee therefor, that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant. The term “Leasehold Mortgage” shall mean, at any point in time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Site and this Ground Lease. It is acknowledged and agreed that, during the Term, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the Term, the Tenant shall provide the Landlord with written notice of the identity, contact information and address for each Leasehold Lender (or the agent authorized to act on behalf of the Leasehold Lender), such notice to be provided to the Landlord by the Tenant within no less than a calendar year within which the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

23.2 Right to Perform for Tenant; Right to Cure. In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and the Landlord shall accept such performance by Leasehold Lender with the same force and effect as if furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing.

23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’s prior written consent, and any such action taken without Leasehold Lender’s consent shall not be binding on the Tenant or Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

 

25


23.4 Delivery of Notices. The Tenant shall promptly provide the Landlord with all pertinent contract information for any Leasehold Lender. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including, without limitation, any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been delivered to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in writing to the Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’s interests in the Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including, without limitation, the acquisition of the Tenant’s interest in this Ground Lease and the Site created thereby in a transaction described in this Section 23 or the taking of possession of the Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender; provided, that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Site.

23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2, the purchaser at any sale of this Ground Lease and the interests in and to the Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including, without limitation, power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Site thereby created under any instrument of assignment or transfer in lieu

 

26


of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Site thereby created.

23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, substantially all, or any part of the Site or the Tenant’s Facilities. Rent shall continue to be due and payable as set forth in this Ground Lease.

23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent domain proceeding of all, substantially all, or any part of the Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Facilities, the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Site created by this Ground Lease and the value of the leasehold improvements located on the Site, up to an amount equaling the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Facilities and/or the Tenant’s interest in, under and to this Ground Lease; provided, that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under applicable law to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this Ground Lease. In the event of a taking of a portion of the Site, the Rent shall be reduced pro rata based upon the portion of the Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease.

 

27


23.9 Estoppel Certificates.

(a) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel”) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under this Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant thereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that this Ground Lease, a true, correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and represents the entirety of the agreement between the Landlord and the Tenant with respect to the Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Landlord’s power and authority to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except for this Ground Lease, there do not exist any other agreements concerning the Site or this Ground Lease, whether oral or written, to which Landlord is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Site, other than those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the Landlord Estoppel, the present lessor under this Ground Lease and owns good and indefeasible title to the Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (xix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

 

28


23.10 No Termination by Confusion. There shall be no termination of this Ground Lease or any interest in this Ground Lease by confusion by reason of the fact that this Ground Lease or such interest therein, may be directly or indirectly held by or for the account of any person who also holds an ownership interest in the Site, nor shall this Ground Lease terminate by confusion by reason of the fact that all or any part of the Site may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any ownership interest in the Site or any interest of the Landlord under this Ground Lease.

23.11 Landlord’s Recognition of Tenant. The Landlord hereby recognizes the Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that the Tenant acquired its interest in this Ground Lease and in and to the Site in accordance with the terms of this Ground Lease.

23.12 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

24.2 Successors. The covenants, agreements, terms, provisions, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties.

24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

 

29


24.6 No Oral Change or Termination. This Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, including the Option Agreement, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

24.9 Litigation. The venue of any litigation shall be solely in Cameron Parish.

24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

24.11 Authority. Each of the Landlord and the Tenant represents and warrants that it has the authority to enter into this Ground Lease, that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date, the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 3, evidencing its authority to execute and perform under this Ground Lease.

24.12 Brokers and/or Real Estate Agents. Each of the Landlord and the Tenant represents, acknowledges and agrees that it is not represented by any real estate broker/agent and that it is not responsible for payment of any commissions to any real estate brokers/agents in connection with this Ground Lease.

24.13 Legal Relationships; Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. This Ground Lease is the product of the Parties joint negotiation and equal drafting thereof. The language of this Ground Lease shall be construed as a whole according to its fair meaning and not construed strictly for or against any of the Parties pursuant to any statue, case law or rule of interpretation or construction to the contrary.

 

30


24.14 Further Assurances. In connection with this Ground Lease and the transactions contemplated hereby, each Party shall execute and deliver any additional documents and instruments and perform any additional acts that may be necessary or appropriate to effectuate and perform the provisions of this Ground Lease and those transactions, including in connection with the requests of any Financing Parties or Leasehold Lender.

24.15 No Waiver or Surrender. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Site and no agreement to accept a surrender of the Site shall be valid unless it is in writing and signed by the Landlord.

24.16 Confidentiality.

(a) Except as necessary in connection with disclosures required by Applicable Laws or Section 24.17, the Landlord agrees to keep in strict confidence, not divulge and guard the accessibility to others within its control (a) the terms and conditions and matters related to this Ground Lease and (b) all information relating to the negotiations of this Ground Lease and the Tenant, or any designee of the Tenant, whether such information is in any way proprietary, strategic or otherwise (collectively, “Confidential Information”). The Landlord may disclose Confidential Information to its attorney, accountant, agent or involved members, commissioners, employees, agents and representatives who “need to know” such Confidential Information for the performance of their respective duties.

(b) Without limiting the foregoing, in the event that the Landlord is required by Applicable Law to disclose any of the Confidential Information in contravention of this Section 24.16, the Landlord will, to the extent legally permissible, provide the Tenant prompt prior written notice thereof and furnish only that portion of the Confidential Information that the Landlord is advised by counsel is legally required and will give the Tenant written notice of the Confidential Information to be disclosed as far in advance as practicable and exercise all reasonable efforts to obtain reliable assurance that such Confidential Information will be treated as confidential and held in the strictest confidence. The Landlord further agrees to treat the information set forth in Section 4 as proprietary trade secret information in its custodial control pursuant to La. R.S. § 44:3.2 and shall, accordingly, not disclose any such information in response to any public records request or otherwise.

24.17 Memorandum of Lease; Public Version. The Parties agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’s interest hereunder; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease.

[Remainder of page left intentionally blank; signatures on following pages]

 

31


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

    LANDLORD:

/s/ Kim Montie

           CAMERON PARISH PORT, HARBOR AND TERMINAL DISTRICT
WITNESS Kim Montie    

 

Acting by and through

/s/ Tianna Dunanay

    CAMERON PARISH PORT COMMISSION
WITNESS Tianna Dunanay      
    By:  

/s/ Howard Romero

    Name: Howard Romero

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Cameron and State of Louisiana, personally came and appeared Howard Romero, who, after being sworn by me, did execute this agreement on the 24th day of October, 2023 at Cameron, State of Louisiana.

    /s/ W. Thomas Barret II    

NOTARY PUBLIC

 

1


    TENANT:

/s/ Witness Signature

    VENTURE GLOBAL CP2 LNG, LLC
WITNESS    

/s/ Witness Signature

           By:  

/s/ Fory L. Musser

WITNESS     Name: Fory L. Musser
    Title: Senior Vice President

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Fory L. Musser, who, after being sworn by me, did execute this agreement on the 24th day of October, 2023 at Arlington, State of Virginia.

     /s/ Michael E. Millan     

NOTARY PUBLIC

 

1


LIST OF EXHIBITS

 

Exhibit 1-A    Legal Description of the Site
Exhibit 1-B    Site Survey
Exhibit 2    Facility Description
Exhibit 3    Tenant’s Resolution

 

1


EXHIBIT 1-A

LEGAL DESCRIPTION OF THE SITE

PARCEL “W”

COMMENCING AT THE RADIAL CORNER OF IRREGULAR SECTION 32, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND CONCRETE MONUMENT AND BEING THE POINT OF BEGINNING; THENCE S.89°08’21”E., A DISTANCE OF 1,803.41 FEET ALONG THE NORTH LINE OF SAID SECTION 32 TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°08’21”E., A DISTANCE OF 1,258.99 FEET ALONG THE NORTH LINE OF SAID SECTION 32 TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°08’21”E., A DISTANCE OF 1,530.81 FEET ALONG THE NORTH LINE OF SAID SECTION 32 TO A POINT BEING MARKED BY A FOUND ONE INCH DIAMETER IRON PIPE; THENCE S.89°08’21”E., A DISTANCE OF 100.19 FEET ALONG THE NORTH LINE OF SAID SECTION 32 TO A POINT BEING MARKED BY A FOUND ONE INCH DIAMETER IRON BAR; THENCE S.89°08’21”E., A DISTANCE OF 270.13 FEET TO THE INTERSECTION OF THE NORTH LINE OF SAID SECTION 32 AND THE RIGHT DESCENDING BANK LINE OF THE CALCASIEU RIVER SHIP CHANNEL; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 36.08’ N.89°08’27”W. OF TRUE POSITION; THENCE S.16°24’04”W., A DISTANCE OF 52.47 FEET ALONG SAID BANK LINE; THENCE S.26°42’11”W., A DISTANCE OF 19.31 FEET ALONG SAID BANK LINE; THENCE S.21°52’07”W., A DISTANCE OF 47.77 FEET ALONG SAID BANK LINE; THENCE S.18°45’55”W., A DISTANCE OF 5.84 FEET ALONG SAID BANK LINE; THENCE S.22°22’52”W., A DISTANCE OF 45.03 FEET ALONG SAID BANK LINE; THENCE S.29°45’33”W., A DISTANCE OF 16.58 FEET ALONG SAID BANK LINE; THENCE S.08°21’35’‘E., A DISTANCE OF 30.42 FEET ALONG SAID BANK LINE; THENCE S.25°36’41”W., A DISTANCE OF 51.35 FEET ALONG SAID BANK LINE; THENCE S.14°54’12”W., A DISTANCE OF 48.78 FEET ALONG SAID BANK LINE; THENCE S.20°26’46”E., A DISTANCE OF 6.23 FEET ALONG SAID BANK LINE; THENCE S.12°14’34”W., A DISTANCE OF 40.46 FEET ALONG SAID BANK LINE; THENCE S.11°48’53”W., A DISTANCE OF 16.80 FEET ALONG SAID BANK LINE; THENCE S.20°48’24”W., A DISTANCE OF 7.07 FEET ALONG SAID BANK LINE; THENCE S.00°08’02”W., A DISTANCE OF 14.24 FEET ALONG SAID BANK LINE; THENCE S.04°07’48”E., A DISTANCE OF 24.71 FEET ALONG SAID BANK LINE; THENCE S.07°36’06”E., A DISTANCE OF 22.60 FEET ALONG SAID BANK LINE; THENCE S.20°22’01”E., A DISTANCE OF 18.77 FEET ALONG SAID BANK LINE; THENCE S.09°18’25”E., A DISTANCE OF 32.67 FEET ALONG SAID BANK LINE; THENCE S.03°13’21”E., A DISTANCE OF 6.53 FEET ALONG SAID BANK LINE; THENCE S.09°09’02”E., A DISTANCE OF 14.38 FEET ALONG SAID BANK LINE; THENCE S.07°36’02”E., A DISTANCE OF 22.71 FEET ALONG SAID BANK LINE; THENCE S.03°18’07”W., A DISTANCE OF 30.89 FEET ALONG SAID BANK LINE; THENCE S.03°28’39”E., A DISTANCE OF 56.69 FEET ALONG SAID BANK LINE; THENCE S.04°22’39”W., A DISTANCE OF 62.11 FEET ALONG SAID BANK LINE; THENCE S.00°14’21”W., A DISTANCE OF 62.00 FEET ALONG SAID BANK LINE; THENCE S.00°28’44”W., A DISTANCE OF 62.00 FEET ALONG SAID BANK LINE; THENCE

 

1


S.01°39’21”W., A DISTANCE OF 62.00 FEET ALONG SAID BANK LINE; THENCE S.02°33’16”W., A DISTANCE OF 55.04 FEET ALONG SAID BANK LINE; THENCE S.07°18’34”W., A DISTANCE OF 7.02 FEET ALONG SAID BANK LINE; THENCE S.26°28’56”E., A DISTANCE OF 16.68 FEET ALONG SAID BANK LINE; THENCE S.36°02’12”E., A DISTANCE OF 13.80 FEET ALONG SAID BANK LINE; THENCE S.54°20’04”E., A DISTANCE OF 13.19 FEET ALONG SAID BANK LINE; THENCE S.43°20’10”E., A DISTANCE OF 11.26 FEET ALONG SAID BANK LINE; THENCE S.35°11’59”W., A DISTANCE OF 19.51 FEET ALONG SAID BANK LINE; THENCE S.15°46’53”W., A DISTANCE OF 4.61 FEET ALONG SAID BANK LINE; THENCE S.15°29’20”W., A DISTANCE OF 20.22 FEET ALONG SAID BANK LINE; THENCE S.17°53’04”W., A DISTANCE OF 13.65 FEET ALONG SAID BANK LINE; THENCE S.20°35’10”W., A DISTANCE OF 21.67 FEET ALONG SAID BANK LINE; THENCE S.25°16’31”E., A DISTANCE OF 10.00 FEET ALONG SAID BANK LINE; THENCE S.19°27’17”W., A DISTANCE OF 18.56 FEET ALONG SAID BANK LINE; THENCE S.29°20’25”E., A DISTANCE OF 51.42 FEET ALONG SAID BANK LINE; THENCE S.12°30’19”W., A DISTANCE OF 13.84 FEET ALONG SAID BANK LINE; THENCE S.08°47’36”W., A DISTANCE OF 16.08 FEET ALONG SAID BANK LINE; THENCE S.16°59’58”E., A DISTANCE OF 20.20 FEET ALONG SAID BANK LINE; THENCE S.24°44’49”W., A DISTANCE OF 14.52 FEET ALONG SAID BANK LINE; THENCE S.27°48’04”W., A DISTANCE OF 49.06 FEET ALONG SAID BANK LINE; THENCE S.26°36’03”E., A DISTANCE OF 20.57 FEET ALONG SAID BANK LINE; THENCE S.07°31’39”E., A DISTANCE OF 20.83 FEET ALONG SAID BANK LINE; THENCE S.10°25’36”E., A DISTANCE OF 10.40 FEET ALONG SAID BANK LINE; THENCE S.19°24’51”W., A DISTANCE OF 21.52 FEET ALONG SAID BANK LINE; THENCE S.47°40’59”W., A DISTANCE OF 15.75 FEET ALONG SAID BANK LINE; THENCE S.10°17’25”W., A DISTANCE OF 17.37 FEET TO THE INTERSECTION OF SAID BANK LINE AND THE SOUTH LINE OF SAID SECTION 32; SAID POINT BEING MARKED BY A FOUND ONE INCH DIAMETER IRON PIPE, OFFSET 27.53’ N.74°07’40”W. OF TRUE POSITION; THENCE N.74°07’40”W., A DISTANCE OF 281.97 FEET ALONG SOUTH LINE OF SAID SECTION 32 TO A POINT BEING MARKED BY A FOUND ONE INCH DIAMETER IRON PIPE; THENCE N.74°07’40”W., A DISTANCE OF 1,588.66 FEET ALONG SOUTH LINE OF SAID SECTION 32 TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.74°07’40”W., A DISTANCE OF 1,582.71 FEET ALONG SOUTH LINE OF SAID SECTION 32 TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER

SAID DESCRIBED PARCEL, CONTAINING 3,207,444.97 SQUARE FEET OR 73.6328 ACRES, MORE OR LESS, IS SITUATED IN SECTION 32, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “W”.

-AND-

PARCEL “X”

COMMENCING AT THE RADIAL CORNER OF IRREGULAR SECTION 32, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND CONCRETE MONUMENT; THENCE S.89°08’27”E., A DISTANCE OF 6,090.25 FEET ALONG THE NORTH LINE OF SAID SECTION 32; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH

 

2


DIAMETER IRON PIPE, OFFSET 96.72’ S.89°08’27”E. OF TRUE POSITION AND BEING THE POINT OF BEGINNING; THENCE S.89°08’27”E., A DISTANCE OF 791.99 FEET ALONG THE NORTH LINE OF SAID SECTION 32 TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°08’27”E., A DISTANCE OF 218.23 FEET ALONG THE NORTH LINE OF SAID SECTION 32 TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°08’27”E., A DISTANCE OF 666.68 FEET TO THE INTERSECTION OF THE NORTH LINE OF SAID SECTION 32 AND THE RIGHT DESCENDING BANK LINE OF THE CALCASIEU RIVER; SAID POINT BEING MARKED BY A FOUND ONE INCH DIAMETER IRON PIPE, OFFSET 55.65’ N.89°08’27”W. OF TRUE POSITION; THENCE S.52°32’18”W., A DISTANCE OF 83.94 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.41°09’12”W., A DISTANCE OF 83.30 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.37°20’27”W., A DISTANCE OF 82.44 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.36°42’25”W., A DISTANCE OF 71.97 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.37°02’44”W., A DISTANCE OF 53.03 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.54°01’56”W., A DISTANCE OF 29.20 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.28°07’10”W., A DISTANCE OF 52.62 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.40°46’44”W., A DISTANCE OF 24.05 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.34°13’07”W., A DISTANCE OF 40.72 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.55°57’01”W., A DISTANCE OF 12.72 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.40°50’00”W., A DISTANCE OF 16.99 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.17°38’41”W., A DISTANCE OF 47.05 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.37°08’54”W., A DISTANCE OF 31.62 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.34°03’50”W., A DISTANCE OF 76.07 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.22°15’24”W., A DISTANCE OF 63.97 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.30°12’17”W., A DISTANCE OF 70.72 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.31°23’47”W., A DISTANCE OF 58.28 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.48°42’27”W., A DISTANCE OF 15.87 FEET ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.26°54’06”W., A DISTANCE OF 67.80 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.22°25’08”W., A DISTANCE OF 67.29 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.22°14’37”W., A DISTANCE OF 66.74 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.25°15’43”W., A DISTANCE OF 70.56 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.25°43’41”W., A DISTANCE OF 65.79 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.35O54’37”W., A DISTANCE OF 79.81 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.33O47’26”W., A DISTANCE OF 72.88 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.26°33’47”W., A DISTANCE OF 68.96 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.28°18’56”W., A DISTANCE OF 72.76 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.34°02’32”W., A DISTANCE OF 71.08 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.45°43’46”W., A DISTANCE OF 83.07 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.55°26’25”W., A DISTANCE OF 42.61 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.52°08’20”W., A DISTANCE OF 57.68 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE; THENCE S.28O23’46”W., A DISTANCE OF 43.36 FEET TO A POINT ALONG SAID RIGHT DESCENDING BANK LINE BEING MARKED BY A FOUND THREE QUARTER INCH DIAMETER IRON PIPE, OFFSET 24.87’ N.58°21’08”W., OF TRUE POSITION; THENCE N.58°21’08”W., A DISTANCE OF 470.88 FEET TO A POINT BEING MARKED BY A FOUND QUARTER INCH DIAMETER IRON PIPE; THENCE S.37°46’20”W., A DISTANCE OF 128.70 FEET TO A POINT BEING MARKED BY A FOUND ONE INCH DIAMETER IRON PIPE; THENCE S.01°56’37”E., A DISTANCE OF 240.01 FEET TO

 

3


A POINT ALONG THE SOUTH LINE OF SAID SECTION 32 BEING MARKED BY A FOUND THREE QUARTER INCH DIAMETER IRON PIPE; THENCE N.74°07’40”W., A DISTANCE OF 262.23 FEET TO THE INTERSECTION OF THE SOUTH LINE OF SAID SECTION 32 AND THE LEFT DESCENDING BANK LINE OF THE CALCASIEU RIVER SHIP CHANNEL; SAID POINT BEING MARKED BY A FOUND FOUR INCH DIAMETER TRANSITE PIPE, OFFSET 69.49’ S.74°07’40”E. OF TRUE POSITION; THENCE N.33°56’33”E., A DISTANCE OF 58.99 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.41°05’48”E., A DISTANCE OF 8.18 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.48O23’36”E., A DISTANCE OF 24.94 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.39°29’01”E., A DISTANCE OF 27.90 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.29°18’35”E., A DISTANCE OF 46.38 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.27°00’23”E., A DISTANCE OF 44.23 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.33°51’32”E., A DISTANCE OF 30.78 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.41°32’29”E., A DISTANCE OF 47.59 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.15°58’03”E., A DISTANCE OF 71.97 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.36°38’36”E., A DISTANCE OF 82.40 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.15°54’03”E., A DISTANCE OF 69.84 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.06°44’35”E., A DISTANCE OF 67.15 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.00°58’45”W., A DISTANCE OF 61.26 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.11°38’43”W., A DISTANCE OF 24.19 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.11°52’50”W., A DISTANCE OF 41.88 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.26O34’52”W., A DISTANCE OF 66.34 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.09°13’56”W., A DISTANCE OF 28.49 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.01°07’35”E., A DISTANCE OF 27.24 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.42°56’29”W., A DISTANCE OF 17.54 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.39°04’54”W., A DISTANCE OF 69.44 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.08°23’56”E., A DISTANCE OF 11.20 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.16°43’58”E., A DISTANCE OF 23.93 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.32°56’00”E., A DISTANCE OF 18.64 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.06°15’09”W., A DISTANCE OF 23.14 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.28°25’18”W., A DISTANCE OF 63.22 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.07°26’42”E., A DISTANCE OF 10.71 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.14°07’14”E., A DISTANCE OF 53.61 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.06°53’58”W., A DISTANCE OF 61.33 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.02°13’45”W., A DISTANCE OF 54.23 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.00°00’31”E., A DISTANCE OF 68.11 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.03°58’57”E., A DISTANCE OF 53.34 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.01°21’06”W., A DISTANCE OF 75.57 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.06°09’54”W., A DISTANCE OF 61.70 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.03°42’31”W., A DISTANCE OF 65.22 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.08°09’27”W., A DISTANCE OF 22.28 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.08°30’58”W., A DISTANCE OF 33.27 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.12°28’44”W., A DISTANCE OF 8.44 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.15°14’25”W., A DISTANCE OF 10.21 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.15°18’29”W., A DISTANCE OF 29.16 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.11°12’29”W., A DISTANCE OF 27.90 FEET TO A POINT ALONG

 

4


SAID LEFT DESCENDING BANK LINE; THENCE N.15°16’44”W., A DISTANCE OF 35.87 FEET TO A POINT ALONG SAID LEFT DESCENDING BANK LINE; THENCE N.13°05’41”W., A DISTANCE OF 7.86 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 1,642,349.56 SQUARE FEET OR 37.7032 ACRES, MORE OR LESS, IS SITUATED IN SECTION 32, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “X”.

 

5


EXHIBIT 1-B

SURVEY MAP OF SITE

[Omitted]


EXHIBIT 2

FACILITY DESCRIPTION

[Omitted]


EXHIBIT 3

TENANT’S RESOLUTION

[Omitted]

Exhibit 10.62

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

STATE OF LOUISIANA

PARISH OF CAMERON

GROUND LEASE AGREEMENT

(351 Acres)

This GROUND LEASE AGREEMENT (this “Ground Lease”) is executed and effective as of March 11, 2019 (the “Ground Lease Commencement Date”), by and between Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Tenant”) and Henry Venture, LLC, a Louisiana limited liability company (the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Cameron Parish, Louisiana, which comprises approximately three hundred fifty-one (351) acres identified herein as the Project Site and as further defined below; and

WHEREAS, the Tenant is desirous of leasing land owned by the Landlord for the construction and development and operation of a natural gas liquefaction facility as generally described in Exhibit 2 (the “Facility”) and other uses permitted by this Ground Lease; and

WHEREAS, the Landlord and the Tenant desire to lease such land in order to develop the land with the Facility and thereby create and provide employment opportunities for the inhabitants of Southwest Louisiana, which will add to the welfare and prosperity of the persons residing within the geographic limits of numerous surrounding Parishes and throughout the State of Louisiana; and

WHEREAS, in accordance with the above, the Tenant has executed this Ground Lease and offers fair value to the Landlord as cause and consideration for this Ground Lease; and

NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this Ground Lease, and the Parties herein covenant and agree as follows:

1. Definitions.

As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

Adjustment Period” has the meaning set forth in Section 4.1(c).

 

1


Affiliate” means any Person controlled by, controlling or under common control with the Landlord or the Tenant, as applicable. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of thirty percent (30%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.

Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Project Site.

Bankruptcy Proceeding” has the meaning set forth in Section 23.10.

Bona Fide Offer” has the meaning set forth in Section 14.3.

Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in the State of New York are authorized or required by law to close.

Consumer Price Index” has the meaning set forth in Section 4.2.

Corps” has the meaning set forth in Section 8.3(a).

Corrective Measures” has the meaning set forth in Section 9.4(b).

CPI Adjustment” has the meaning set forth in Section 4.1.

CPI Disagreement Notice” has the meaning set forth in Section 4.2.

CPI Notice” has the meaning set forth in Section 4.2.

CPI Percentage Increase” has the meaning set forth in Section 4.2.

Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Law relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

Event of Default” has the meaning set forth in Section 15.1.

Extended Term” has the meaning set forth in Section 3.2(a).

Facility” has the meaning set forth in the Recitals hereof.

 

2


Facility Contractors” means, collectively, the Persons engaged by the Tenant to construct the Facility and/or develop the Project, Project Site and/or Improvements.

Facility Contracts” means, collectively, the contracts entered into by the Tenant in connection with the design, construction, equipment procurement, operation and maintenance of the Facility and/or the Project, Project Site and/or Improvements.

Fair Market Value” means the value determined pursuant to the process set forth in Section 14.5.

Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Project or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders.

First Appraiser” has the meaning set forth in Section 14.5.

Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include, but not be limited to, the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, droughts, floods, washouts, explosions, breakage or accident or necessity of repairs to machinery or equipment or lines of pipe; (ii) weather related events affecting an entire geographic region; (iii) acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, terrorism, discovery of burial grounds or human remains or legally protected artifacts, insurrections or wars; (iv) the failure or interruption of performance by the Tenant’s engineering, procurement and construction contractor or any subcontractors of such contractor to the extent caused by an event of Force Majeure under this Ground Lease; (v) the failure or interruption of performance by the Tenant’s suppliers by reason of such supplier’s valid declaration of an event that would constitute an event of force majeure under the Tenant’s contract with such supplier; (vi) governmental actions such as necessity for compliance with any court order, law, statute, ordinance, regulation, or policy having the effect of law promulgated by a Governmental Authority having jurisdiction, or that restrict the Tenant’s ability to reasonably construct and/or operate the Facility and/or Project or any delay in issuance or effectiveness of any Governmental Approval that has been properly applied for by the Tenant that is required to construct and/or operate the Facility and/or Project.

Governmental Approval” means any authorization, waiver, consent, approval, license, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority.

Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

 

3


Ground Lease” has the meaning set forth in the Preamble hereof.

Ground Lease Commencement Date” has the meaning set forth in the Preamble hereof.

Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

Hazardous Substances Law” means any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including, but not limited to, the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent it relates to the handling of and exposure to hazardous or toxic materials or similar substances.

Improvements” means any and all improvements made by the Tenant, in its sole discretion, to the Project Site in conformity with Applicable Law, including but not limited to, improvements relating to the loading, unloading, handling, treatment, processing, producing, transporting, distributing, selling, metering and/or storing of (i) natural gas, natural gas liquids, and other natural gas products, derivatives and by-products and (ii) other petroleum and

 

4


hydrocarbon liquids, gases, products, derivatives and by-products, including but not limited to (A) the importation, regasification, production, exportation, liquefaction, refinement, enhancement, other treatment and transportation (including by ship, pipeline, truck or rail) of LNG, and LNG by-products and additives and (B) the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of any improvements, component parts and other constructions, fixtures, facilities, equipment and/or appurtenances (including natural gas pipelines, natural gas liquids extraction, processing and delivery facilities, acid gas removal units, natural gas liquefaction trains, LNG regasification facilities, and other treatment facilities, cryogenic pipelines, LNG storage tanks, petroleum and other hydrocarbon liquids storage facilities, nitrogen storage and processing facilities, power generation and transmission infrastructure, marine, rail and trucking receipt, delivery and servicing facilities (including piers, marine terminals, bulkheads, wharfs, docks, inlets, wetslips, moonpools, moorings, jetties, and loading and unloading equipment), other utilities, facilities (including berms, open space, security fencing, control rooms, offices, warehouses, laydown areas, parking and yards), roads, and modifications to existing roads, in each case, necessary, ancillary or desirable to the Tenant in connection with the foregoing.

Initial Term” has the meaning set forth in Section 3.1.

Landlord” has the meaning set forth in the Preamble hereof.

Landlord Estoppel” has the meaning set forth in Section 23.11(a).

Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, affiliates, invitees, agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Project Site and/or Landlord’s Improvements.

Landlord’s Event of Default” has the meaning set forth in Section 16.1.

Landlord Indemnitee” has the meaning set forth in Section 9.1.

Landlord’s Improvements” has the meaning set forth in Section 6.1.

Lease Year” means a period of twelve (12) consecutive full calendar months. The first Lease Year shall begin on the Ground Lease Commencement Date. Each succeeding Lease Year shall commence upon the anniversary of the first day of the previous Lease Year.

Leasehold Lenders” has the meaning set forth in Section 23.1.

Leasehold Loan” has the meaning set forth in Section 23.1.

Leasehold Mortgage” has the meaning set forth in Section 23.1.

 

5


Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

LNG” means liquefied natural gas.

Minerals” has the meaning set forth in Section 8.3(b).

New Lease” has the meaning set forth in Section 23.9(a).

Non-Disturbance Agreement” has the meaning set forth in Section 23.11(c).

Option Agreement” means the Real Estate Lease Option Agreement between the Landlord and the Tenant, dated as of October 16, 2015.

Party” or “Parties” has the meaning set forth in the Preamble hereof.

Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

Project” means the development, permitting, financing, construction, ownership, operation and/or maintenance of the Facility and the Improvements on the Project Site.

Project Site” means the real (immovable) property of approximately three hundred fifty-one (351) acres described in the legal description set forth in Exhibit 1-A, and illustrated by the Survey Maps attached as Exhibit 1-B, including any waterway areas, upon which the Facility and other Improvements will be located and which real (immovable) property is owned by the Landlord.

Property Taxes” means all real and personal property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

Removal Period” means the period of time that is required by the Tenant to remove any and all of the Tenant’s Property, including the Facility and/or Improvements, from the Project Site in accordance with Section 7.1.

Rent” has the meaning set forth in Section 4.1.

Second Appraiser” has the meaning set forth in Section 14.5.

Surface Waiver” has the meaning set forth in Section 8.3(b).

 

6


Survey Map” means each of (i) the map of survey of dated June 30, 2015, by Lonnie G. Harper & Associates, Inc., (ii) the map of survey of dated June 22, 2015, by Lonnie G. Harper & Associates, Inc., and (iii) the map of survey of dated June 22, 2015, by Lonnie G. Harper & Associates, Inc., each attached as Exhibit 1-B.

Tenant” has the meaning set forth in the Preamble hereof.

Tenant Estoppel” has the meaning set forth in Section 23.11(b).

Tenant Indemnitee” has the meaning set forth in Section 9.3.

Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Project Site, including the Facility and any Improvements.

Third Appraiser” has the meaning set forth in Section 14.5.

2. Ground Lease Premises.

2.1 Date. The date of this Ground Lease is the Ground Lease Commencement Date.

2.2 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of the rents and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does lease to the Tenant and the Tenant hereby leases from the Landlord, the Project Site and Landlord’s Improvements.

2.3 Servitudes. In addition, the Landlord shall without cost to the Tenant, grant from time to time to the Tenant and others designated by the Tenant (including any Affiliate of the Tenant) any easements, servitudes, and rights of way for access and electricity, communications, gas, water, sewer and other utility lines, products and materials from and to the Project Site over land and waterways sufficient to permit the Tenant to accomplish its purposes in connection with the Project.

3. Term

3.1 Initial Term. The initial term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on the thirtieth (30th) anniversary of the last day of the month immediately preceding the Ground Lease Commencement Date (the “Initial Term”).

 

7


3.2 Extensions.

(a) In consideration of and conditioned upon there being no uncured Event of Default on the part of the Tenant at the time an option is exercised, the Landlord hereby grants unto the Tenant the option to lease the Project Site for four (4) additional ten (10) year terms. If the extension option is exercised in accordance with Section 3.2(b), the first of said additional terms shall commence upon the expiration of the Initial Term and extending for a period of ten (10) years and each of said additional terms commencing upon the expiration of the then current additional term and extending for a period of ten (10) years. Each of such additional terms is referred to herein as an “Extended Term”.

(b) The option to extend this Ground Lease of the Project Site as set forth in Section 3.2(a) must be exercised in each case, if at all, by written notice from the Tenant to the Landlord on or before the date that is three (3) months prior to the expiration of the Initial Term or then current Extended Term, as applicable. The failure of the Tenant to timely exercise the first Extended Term or any subsequent Extended Term shall automatically terminate the right of the Tenant to exercise its option to lease the Project Site in any subsequent Extended Term.

(c) All the terms and conditions of this Ground Lease shall be applicable to any Extended Term and the Rent payable by the Tenant for any Extended Term shall be in accordance with the provisions set forth in Section 4.

4. Rent.

4.1 Rent. Commencing upon the Ground Lease Commencement Date, the initial rent for the Project Site (“Rent”) shall be [***], payable in equal installments of [***] per month, adjusted upward every five (5) years thereafter during the Initial Term and during any Extended Term by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment during any Adjustment Period (as defined below) of greater than [***]. The period of time from the Ground Lease Commencement Date through March 11, 2024, and each five (5) year period thereafter shall be defined herein as an “Adjustment Period.” Any upward adjustment based on a CPI Percentage Increase (as defined below) to any payment under this Ground Lease shall hereinafter be referred to as a “CPI Adjustment.” Such Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month; provided however, that (i) the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; and (ii) the first payment of Rent due upon the commencement of any new Adjustment Period will be owed and paid one month after the commencement of that Adjustment Period, in order to permit the Tenant to calculate the CPI Percentage Increase, as set forth below.

 

8


4.2 CPI Adjustment. If CPI Percentage Increase (as defined below) is more than [***] for the relevant Adjustment Period, then the Rent payable during that Adjustment Period shall be adjusted upward by a percentage equal to the CPI Percentage Increase (as defined below) applicable to such Adjustment Period, but not to exceed an adjustment during any Adjustment Period of greater than [***]. The term “Consumer Price Index” shall mean the unadjusted Consumer Price Index for All Urban Workers, U.S. City Average, All Items, 1982-84=100, calculated and published by the United States Department of Labor, Bureau of Labor Statistics. The “CPI Percentage Increase” shall mean,with respect to any Adjustment Period, [***]. For the avoidance of doubt, no CPI Adjustment shall be made to any payment due under this Ground Lease for any Adjustment Period if the result of such CPI Adjustment would be to (a) reduce the amount of such payment to an amount that is less than the amount of such payment due for the immediately preceding Adjustment Period or (b) to raise the amount of such payment to an amount that is greater than [***]. For illustrative purposes only, [***]. The CPI Percentage Increase for any Adjustment Period shall be calculated by the Tenant, and the Tenant shall deliver written notice to the Landlord describing such calculation in reasonable detail (a “CPI Notice”) no later than thirty (30) days after the commencement of any Adjustment Period. If the Landlord disagrees with the Tenant’s calculation of the CPI Percentage Increase, then the Landlord shall deliver to the Tenant written notice, describing the basis for such disagreement in reasonable detail (a “CPI Disagreement Notice”), not later than thirty (30) days after delivery of the CPI Notice. If the Landlord fails to deliver a CPI Disagreement Notice within thirty (30) days after delivery of any CPI Notice, then the Landlord shall be conclusively deemed to have agreed with the calculation of the CPI Percentage Increase set forth in such CPI Notice.

4.3 Due Date. Except as otherwise provided in this Ground Lease, all Rent payments shall be due in advance on the 1st calendar day of each month and payable by the 15th calendar day of each month during the entire term of this Ground Lease. If the 15th calendar day of a month falls on a day this is not a Business Day, then Rent shall be payable on the following Business Day.

4.4 Place of Payment. Except as otherwise provided herein, Rent shall be payable by check or wire transfer at the following address or via wire instructions set forth below, or to such other place as the Landlord may specify and the Tenant deem acceptable, as hereinafter provided, from time to time: [***], or in accordance with the following bank wire instructions.

 

9


Bank Name:          

Bank Address:          

Account Name:          

Account No.:          

Routing No.          

5. Net Lease; Taxes and Utility Expenses.

5.1 Net Lease. This Ground Lease is a net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs, if any, of every kind and nature whatsoever relating to the Project Site except as expressly otherwise provided in this Ground Lease.

5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and Governmental Approval fees applicable to the Facility during the term of this Ground Lease.

(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on or related to the Project Site during the term of this Ground Lease. The Landlord shall promptly provide all Property Tax bills to the Tenant when they become available. Upon the latter of (i) one (1) month after receipt of such Property Tax bill from the Landlord or (ii) the due date of any such Property Taxes, the Tenant shall provide the Landlord with reasonable written evidence from the Cameron Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

5.3 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost, electricity, telephone, water, sewerage, gas, and other utility services to the Project Site; provided, however, the Landlord shall cooperate and facilitate at its cost the contracting of any easements, servitudes and/or rights of way, and grant easements, servitudes and rights of way in accordance with Section 2.3, as required by the Tenant for such utility connections and/or services.

6. Tenant and Landlord Improvements.

6.1 Landlord’s Improvements.Landlord’s Improvements” are any and all improvements to the immovable property of the Project Site and any and all movable property in existence on the Project Site at the time of the Ground Lease Commencement Date. There are no Landlord’s Improvements.

 

10


6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install on the Project Site, the Facility and any Improvements during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply in conformity with Applicable Laws. The Tenant shall be permitted to make any changes, improvements or alterations to the Project Site, including without limitation the Facility and any Improvements to the Project Site, during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. During the term of this Ground Lease, the Tenant has the right to make any changes, alterations, and/or improvements with respect to the Project as long as such changes, alterations, and/or improvements comply with Applicable Laws.

6.3 Governmental Approvals. The Landlord will cooperate and assist (and never oppose) the Tenant in obtaining any and all Governmental Approvals deemed necessary by the Tenant for the Facility and all other Improvements to the Project Site, including with respect to Governmental Approvals from the Federal Energy Regulatory Commission and the Department of Energy. The Landlord will hereafter continue to be obligated to execute appropriate documentation to waive its right to require wetlands mitigation to be completed on the Project Site or other real (immovable) property owned by the Landlord, in such form as necessary to allow the Tenant to complete such wetlands mitigation at locations other than other real (immovable) property owned by the Landlord.

6.4 Tenant’s Property. The Tenant’s Property shall at all times be and remain the sole property of the Tenant.

6.5 Maintenance of Improvements.

(a) Tenant’s Obligation to Maintain. During the Initial Term or any Extended Term, as applicable, the Tenant will keep in reasonably good state of repair the Facility, the Improvements, open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Project Site by the Tenant, and the Tenant will, in its sole discretion and cost, repair such property as often as may be necessary in order to keep the Facility and Improvements in reasonably good repair and condition, except as set forth in Section 6.5(b).

(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease, the Landlord has no obligation to maintain the Project Site, Improvements and/or Landlord’s Improvements (if any) during the Initial Term and/or any Extended Term. Except as described in Section 6.1, the Landlord agrees that there will be no such Landlord Improvements on the Project Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Project Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

 

11


7. Tenant’s Surrender of Project Site.

7.1 Surrender at End of Ground Lease. Subject to Section 6.4 and subject and subordinate to Section 23 and the rights of any Leasehold Lender under any Leasehold Mortgage, the Tenant shall and will on the last day of the Initial Term, or if extended, on the last day of the Extended Term hereof, surrender and deliver the Project Site to the Landlord, in good condition as is reasonably practicable (except as provided in Section 6.5 or Section 13), excepting normal wear and tear. If this Ground Lease is terminated for any reason or upon the expiration of the Initial Term and/or Extended Term (if extended) of this Ground Lease, the Tenant shall in good faith proceed with (i) any removal of the Facility and any and all Improvements and (ii) restoration, if any, of the Project Site to its condition prior to construction of the Facility and/or Improvements, in accordance with Applicable Laws. The Tenant shall have all access rights to the Project Site that are necessary to remove any and all of the Tenant’s Property, including the Facility and/or Improvements. The Tenant shall also comply as required by any federal regulations of the Federal Energy Regulatory Commission or any other federal authority with respect to the Facility on the Project Site.

7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date the Tenant shall assume full dominion, control and responsibility for the Project Site, except to the extent specifically provided herein, to the extent provided under LSA – R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real (immovable) or personal (movable) property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its officers, representatives, agents, or employees or the Landlord’s misrepresentations or its breach of or default under this Ground Lease.

7.3 Holding Over. Except for a Removal Period, if the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, and shall not constitute a renewal or extension of the term of this Ground Lease.

8. Use.

8.1 Permitted Uses; Compliance with Laws; Permits. The Tenant may use the Project Site for any and all uses desired by the Tenant in compliance with all Applicable Laws. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the construction and maintenance of the Facility, the Improvements and/or for the Tenant’s use or activities on the Project Site. The Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Project and security of the Project Site, including, but not limited to, the timely filing, implementation, and enforcement of any security plan required by Applicable Laws. Any fine or penalty imposed by any Governmental Authority solely caused by the failure of the Tenant to comply with this provision, including any fine or penalty imposed upon the Landlord as owner of the Project Site as solely caused by the failure of the Tenant to comply with this provision, shall be the sole responsibility of the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall indemnify and hold harmless the Landlord from the payment of any such fine or penalty, and the Tenant may pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord.

 

12


8.2 Use of Water Frontage. To the extent the Project Site is bordered by water frontage, the Tenant shall have any and all rights, including without limitation any and all riparian rights, to use any and all of any such water frontage and water bottom of the Project Site, including without limitation, the Landlord’s Improvements (if any) and the area between the water frontage of the Project Site to the Ship Channel and/or the area between the water frontage of the Project Site to Gulf of Mexico, for mooring of vessels and/or for any and all other uses allowed under Applicable Laws; and the Landlord shall not have the right to use the water frontage of the Project Site, including without limitation all aforementioned areas, for mooring of vessels or any other uses without the prior written consent of the Tenant. It is expressly understood that the Tenant’s consent shall be given or withheld in the Tenant’s sole discretion, and if granted, would be in accordance with any security plan of the Tenant.

8.3 Dirt Moving Activities; Permits; Timber.

(a) The Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Project Site, to the Project Site, and from portions of the Project Site to other portions of the Project Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Project Site and may do so in its discretion. The Tenant shall have the right to remove soil and spoil from, and to add fill to, the Project Site and to dredge the slip and turning basin and dredge and widen the Calcasieu Ship Channel, and deposit the dredge spoils on the Project Site (as allowed by Applicable Laws), in each case in connection with the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of the Facility, and for the purpose of constructing, creating, expanding, operating and maintaining a marine terminal and ship turning basin. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Project Site, including without limitation, for any Improvements, reclamation of lands, erosion control, attainment of spoil, easements/servitudes and/or rights of way; provided, that all costs associated with such efforts shall be the responsibility of the Tenant. Except only as provided in Section 8.3(b), the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Project Site, and all other rights on and to the Project Site. Any activities of the Landlord and/or its lessees or assignees or any other party shall not adversely affect the Project Site or the Facility or interfere with the Tenant’s operations or rights under this Ground Lease in any way. Nothing herein is intended to preclude the Landlord from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation. The Tenant may freely remove any timber which is standing or lying on the Project Site as the Tenant deems necessary for the Tenant’s intended use of the Project Site. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights below the surface of the Project Site.

 

13


(b) To the extent the Landlord holds any rights to oil, gas, or other minerals (“Minerals”) in the Project Site, the Landlord waives any and all rights of the Landlord or its lessees or assignees to use the surface of the Project Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the term of this Ground Lease, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means consistent with the terms and conditions of this Section 8.3(b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Facility or interfere with the Tenant’s operations or rights under this Ground Lease in any way.

8.4 Crossing. The Landlord shall assist the Tenant in the Tenant’s efforts to develop, at the Tenant’s cost, any roads and/or crossings or other Improvements across the Project Site and boundary lines of the Project Site to the adjacent land, including relocation of utilities, providing culverts for storm water drainage, and any other Improvements. The Tenant or others, excluding the Landlord, will pay the cost to relocate or modify the infrastructure for these roads and/or crossings and/or other Improvements.

8.5 Pipelines; Rights of Way. If at any time the Tenant notifies the Landlord that the Project requires an off-Project Site pipeline and/or pipeline servitude for the development of the Project at the Project Site, the Landlord shall grant (with respect to its own real (immovable) property), or use its best efforts to cause the applicable landowners and Governmental Authorities to grant, the pertinent approvals to achieve the pipeline and/or pipeline right of way.

9. Indemnification.

9.1 Tenant’s General Agreement to Indemnify. The Tenant releases the Landlord, its officers, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, witness fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Landlord Indemnitee arising out of (i) the use or occupancy of the Project Site by the Tenant, its officers, representatives, agents, and employees, (ii) the construction or operation of the Project by the Tenant, its officers, representatives, agents, and employees, (iii) any claim arising out of the use, occupancy, construction or operation of the Project Site by the Tenant, its officers, representatives, agents, and employees, and (iv) activities on or about the Project Site by the Tenant, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, operation, maintenance, or repair of the Facility, the Improvements, or the Project Site by the Tenant, its officers, representatives, agents, and employees; provided, however, that any such

 

14


claim, liability, obligation, damage or penalty arising as a result of the negligence or willful misconduct of any Landlord Indemnitee shall be excluded from this indemnity. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9.2 and 9.4 and not this Section 9.1.

9.2 Tenant’s Environmental Indemnification. For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with all Environmental Laws applicable to the Tenant, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Project Site. The Tenant agrees to indemnify and hold harmless the Landlord Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorney, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth above in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Project Site or any violation of any Environmental Law with respect to the Project Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, and maintenance activities or facilities and not caused by the Landlord’s Activities or Landlord’s Improvements.

9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Project Site by the Landlord, its officers, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Project Site by the Landlord, its officers, representatives, agents, and employees, and (iii) activities on or about the Project Site by the Landlord, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation, damage or penalty arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope but not be limited to any and all claims or actions for wrongful death, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.4 and not this Section 9.3.

 

15


9.4 Landlord’s Environmental Indemnification.

(a) For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Project Site. The Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorneys, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances, or (ii) any actual or alleged violation of Environmental Laws, in the case of each of subclauses (i) and (ii), where the presence, discharge or release of such Hazardous Substances or violation of Environmental Law arises or occurs (1) at, on or from the Project Site on or prior to the Ground Lease Commencement Date or (2) at, on or from the Project Site or any other site as a result of or relating to the Landlord’s Activities or facilities or Landlord’s Improvements, whether before, on or after the Ground Lease Commencement Date, or (iii) the Landlord’s breach of the covenant set forth above in this Section 9.4 or (iv) any environmental condition of contamination on the Project Site or any violation of any Environmental Law with respect to the Project Site to the extent occurring after the Ground Lease Commencement Date and caused by the Landlord’s Activities or facilities.

(b) If Hazardous Substances become present or are discharged onto the Project Site as a result of the Landlord’s Activities or otherwise exist at the Project Site on or prior to the Ground Lease Commencement Date, the Tenant shall so notify the Landlord in writing as soon as practicable after the Tenant’s discovery thereof. Except with respect to Hazardous Substances that become present or are discharged onto the Project Site as a result of the Landlord’s Activities, such discovery and notice to the Landlord must occur within the Initial Term of this Ground Lease for the Landlord to have any obligation to perform any Corrective Measures (as hereinafter defined). Except as provided in the following sentence, upon receipt of such notice from the Tenant, the Landlord shall have a reasonable period of time to undertake, at its own expense, but subject to a limit of $5,000,000, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority (“Corrective Measures”), except that such Corrective Measures shall not unreasonably interfere with the construction, operation or maintenance of the Facility and/or interfere the Improvements by Tenant. At its discretion, upon written notice to the Landlord, the Tenant shall have the right to undertake such Corrective Measures and the Landlord shall reimburse the Tenant up to a total amount of $5,000,000 (or Tenant may offset against Rent) for its reasonable and necessary documented costs therefor within thirty (30) days after receipt of an invoice by the Landlord (including any costs associated with the work stoppage or interference with the ability of any Facility Contractor to perform its respective obligations under the Facility Contracts (including mobilization and de-mobilization costs, suspension costs, storage costs, rescheduling penalties, and all other direct and indirect costs incurred by the Tenant or any Facility Contractor (and its respective subcontractors) as a result of any delay caused by such Corrective Measures)). The Party not controlling the Corrective Measures under this Section 9.4(b) shall have a reasonable right of participation in the Corrective Measures, consisting of the right to (i) receive

 

16


copies of material reports, work plans and correspondence relating to the Corrective Measures, (ii) the right to review and comment on draft reports and work plans (and all prompt and reasonable comments shall be considered and addressed by the controlling Party in good faith), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.4(b) shall not supersede or diminish the provisions or the Landlord’s obligations under Section 9.4(a).

9.5 Survival of Indemnities. The foregoing indemnities shall survive the Initial Term, any Extended Term, and any Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

10. Insurance.

10.1 Tenant Insurance. The Tenant shall carry or cause to be carried commercial general liability insurance with respect to the Project Site and the uses and activities of the Tenant thereon with minimum limits of [***]. The Tenant may elect to be self-insured in amounts greater than those minimum limits. In the event the Tenant procures commercial general liability insurance, the Landlord will be named as an additional insured.

10.2 Landlord Insurance. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Project Site and/or any activities of the Landlord with respect to the Project Site in its reasonable business discretion. The Landlord may elect to be self-insured.

11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. The Landlord shall not create or permit to be created or to remain in connection with the Project Site, the Facility, the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Project Site or upon the Landlord’s interest in the Project Site or upon the Tenant’s interest in its leasehold of the Project Site, in accordance with Section 11.2.

11.2 Discharge of Liens.

(a) If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Project Site or any part thereof in connection with the Facility, the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Project Site or any part thereof in connection with the Facility, the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

 

17


(b) If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such Lien by deposit or by bonding proceedings. Any amount so paid by the non-responsible Party and all costs and expenses incurred by the non-responsible Party in connection therewith, including reasonable attorneys’ fees together with interest thereon at one percent (1%) per annum above the Wall Street Journal Prime Rate of interest published from time to time in the Wall Street Journal, from the respective dates of the non-responsible Party’s making of the payment or incurring of the cost and expense, shall constitute either additional rent payable by the Tenant under this Ground Lease or an offset against Rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Project Site, including without limitation, any liabilities, obligations and/or debts owed to laborers, vendors, brokers, materialmen, and other service providers, and then offset against the Rent any such amount(s) paid by the Tenant.

12. Entry on Premises by Landlord, Etc.

The Landlord and its representatives shall have no right to enter the Project Site, except as specifically authorized from time to time in advance in writing by the Tenant after written notice to the Tenant of such request by the Landlord; and such authorization shall be in the Tenant’s sole discretion, and if/when granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of the Tenant. Such entry on the Project Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions such that access to certain sections of the Project Site will be restricted.

13. Destruction by Fire or Other Casualty.

If the Facility or any Improvements erected on the Project Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the willful misconduct of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Facility or the Improvements. In the event that the Tenant so decides not to restore or reconstruct the Facility or the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove any ruins or rubble remaining on the Project Site at the Tenant’s sole cost and expense.

 

18


14. Assignment; Subleasing; Right of First Refusal.

14.1 Restrictions on Landlord. The Landlord shall not assign this Ground Lease or sell the Project Site, in whole or in part, (including without limitation by transfer of control or otherwise) without the prior written consent of the Tenant. This Ground Lease shall inure to the benefit of and shall be binding upon the Landlord’s permitted assigns.

14.2 Restrictions on Tenant. Subject to the provisions of Section 23, the Tenant shall not assign this Ground Lease, in whole or in part, without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least thirty (30) days prior written notice of any proposed assignment, together with a copy of the proposed assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing, including to a Leasehold Lender, (ii) to a Leasehold Lender or any purchaser upon a foreclosure of a Leasehold Mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a Leasehold Mortgage, (iii) to any Affiliate or member of the Tenant, (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, or (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder. The Tenant shall not sublease all or any portion of the Project Site without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed or conditioned.

14.3 Right of First Refusal. During the Initial Term or any Extended Term of this Ground Lease, the Landlord may not transfer a portion of the Project Site and may only transfer the entire Project Site through a bona fide sale in exchange for a sum certain of money. If the Landlord, during the Initial Term or any Extended Term of this Ground Lease, makes a bona fide offer to sell or receives a bona fide offer from a third party to buy or acquire (individually and collectively a “Bona Fide Offer”) all or any portion of the Project Site separately or as a part of a larger parcel of which the Project Site is a part, the Landlord will promptly, within ten (10) Business Days of such making or receipt, give written notice to the Tenant of the terms of the Bona Fide Offer made or received, including the cash price attributable to the Project Site. If the sale is a tract of which the Project Site is a part, then the cash price attributable to the Project Site will be that part of the cash price multiplied times a fraction, the denominator of which is the total number of acres in the Project Site and the numerator of which is the total number of acres in the larger tract to be sold. The notice shall also state the other terms and conditions of the proposed sale and the Landlord’s willingness to sell for that cash price and on those terms. Upon receiving the notice, the Tenant may exercise the right, in the manner specified below, to purchase either the property described in the Bona Fide Offer or the Project Site (or part thereof) at the lower of: (i) the stated cash price in the Bona Fide Offer or (ii) Fair Market Value, which shall not include any value of the Ground Lease, the Facility, the Improvements and/or Landlord’s Improvements in the determination of the Fair Market Value, pursuant to the process described in Sections 14.3 through 14.6. This Section 14.3 does not apply to transfers pursuant to successions or donations executed in accordance with Louisiana law.

 

19


14.4 Exercise of Right of First Refusal. If the Tenant elects to purchase the property or Project Site described in the Bona Fide Offer under the provisions of Section 14.3, or if the Tenant elects to seek the Fair Market Value under the provisions of Section 14.3, the Tenant must notify the Landlord of such election, doing so in writing delivered to the Landlord within thirty (30) Business Days after the date of the Landlord’s written notice to the Tenant of the Bona Fide Offer. If the Tenant elects to refuse the Bona Fide Offer, the Tenant need take no action whatsoever; further, if the Tenant fails to deliver to the Landlord a notice of the Tenant’s election within the time required for such notice, the Tenant will be deemed to have refused the Bona Fide Offer. If the Tenant refuses, or is deemed to have refused, the Bona Fide Offer, the Landlord is free to sell the property pursuant to the Bona Fide Offer subject to this Ground Lease, any New Lease and any Non-Disturbance Agreement, and continuation of the leasehold interest created by this Ground Lease and any New Lease.

14.5 Fair Market Valuation. If the Tenant elects to seek the Fair Market Value under the provisions of Section 14.3, then the Tenant shall notify the Landlord of the Tenant’s proposed Fair Market Value for the property or the Project Site, as the case may be. Thereafter, for a period of thirty (30) days following such notice the Parties shall in good faith attempt to agree upon the Fair Market Value. If the Parties do not agree upon the Fair Market Value within such thirty (30) days, each of the Parties shall within the next thirty (30) days appoint a qualified appraiser to appraise the Fair Market Value (the “First Appraiser” and the “Second Appraiser”) by notice to the other Party. If the Second Appraiser is not timely designated, the determination of the Fair Market Value shall be made solely by the First Appraiser. The First Appraiser, or each of the First Appraiser and the Second Appraiser if the Second Appraiser is timely designated, shall submit its determination of the Fair Market Value to the Parties within thirty (30) days of the date of its selection (or the selection of the Second Appraiser, as applicable). If there are two (2) appraisers and their respective determinations of the Fair Market Value vary by less than ten percent (10%) of the higher determination, the Fair Market Value shall be the average of the two determinations. If such determinations vary by ten percent (10%) or more of the higher determination, the two appraisers shall promptly designate a third appraiser (the “Third Appraiser”). Neither the Tenant nor the Landlord shall provide, and the First Appraiser and Second Appraiser shall be instructed not to provide, any information to the Third Appraiser as to the determinations of the First Appraiser and the Second Appraiser or otherwise influence such Third Appraiser’s determination in any way. The Third Appraiser shall submit its determination of the Fair Market Value to the Parties within thirty (30) days of the date of its selection. The Fair Market Value shall be equal to the average of the two closest of the three determinations. The determination of the Fair Market in accordance with the foregoing procedure shall be final and binding on the Parties. If any appraiser is only able to provide a range in which Fair Market Value would exist, the average of the highest and lowest value in such range shall be deemed to be such appraiser’s determination of the Fair Market Value. Each appraiser selected pursuant to the provisions of this Section 14.5 shall be a qualified Person with prior experience in appraising industrial lands in south Louisiana and that is not an interested Person with respect to either Party or such Party’s Affiliates. If the Tenant has invoked this process and when the Fair Market Value has been determined, then the Tenant must notify the

 

20


Landlord in writing within thirty (30) days that the Tenant elects to purchase the property or Project Site at the lower of either the Fair Market Value determined or the Bona Fide Offer; and if the Tenant fails to notify the Landlord within this thirty (30) day period, then the Landlord is free to sell the property or Project Site pursuant to the Bona Fide Offer subject to this Ground Lease and continuation of the leasehold interest created by this Ground Lease.

14.6 Continuation of Right. If for any reason the Project Site is not sold by the Landlord following a Bona Fide Offer from a third party, the right of first refusal granted and described in the preceding Sections 14.1 through 14.5 shall continue in full force and effect, on the same terms and conditions.

15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of fifteen (15) days after written notice thereof from the Landlord to the Tenant.

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15.1(a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Project Site or discharge from the Project Site shall not constitute an Event of Default.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages; Termination. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default, the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the rights of the Tenant under this Ground Lease, the Tenant shall be liable for such reasonable damages unless such Event of Default is reasonably remedied in a timely manner and all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default, together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and

 

21


payable, and all costs and expenses reasonably incurred by or on behalf of the Landlord as a result of the Event of Default, including reasonable attorneys’ fees, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective and is not valid if the Landlord does not give prior written notice to the Tenant pursuant to Section 15.1.

(b) Landlord’s Right to Cure Tenant’s Event of Default. Upon the occurrence of an Event of Default of the Tenant which is not cured or having commenced curing by the Tenant within sixty (60) days as provided in Section 15.2(b), then, subject to the prior written consent of any Leasehold Lender under Section 23, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others to cure the Event of Default. The Tenant shall be responsible for all costs, including attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord.

15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Project Site to the Landlord, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Project Site and may have, hold, and enjoy the Project Site; and (ii) all obligations of the Tenant hereunder for additional rent or any portion thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. In the event of any termination, the Landlord shall be under a duty to seek a successor tenant. If the Landlord obtains a successor tenant during what would have been the remainder of the term of this Ground Lease, the Tenant shall receive a credit for rentals collected from said successor tenant for the remaining term of this Ground Lease. If no successor tenant is obtained, the Tenant shall be liable for Rent obligations otherwise provided for in this Ground Lease.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Project Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

 

22


16. Events of Default of the Landlord.

16.1 Landlord’s Event of Default; Right to Cure. Any failure of the Landlord to perform and/or to comply with any of its obligations, covenants, agreements, terms, or conditions contained in this Ground Lease shall constitute a “Landlord’s Event of Default” hereunder. The Landlord shall have sixty (60) days after notice by the Tenant to the Landlord of Landlord’s Event of Default to fully cure Landlord’s Event of Default.

16.2 Tenant’s Remedies; Cure. In the event of a Landlord’s Event of Default that is not fully cured under Section 16.1, in addition to all other remedies available to the Tenant, the Tenant may cancel this Ground Lease by written notice to the Landlord. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof, and shall be immediately payable to the Tenant. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default that is not fully cured under Section 16.1.

16.3 Tenant’s Right to Cure Landlord’s Event of Default. Upon the occurrence of a Landlord’s Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord’s Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others, purchasing the required goods or services and procuring necessary insurance. The Landlord shall be responsible for all costs including attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

17. Mutual Obligations.

17.1 Late Charges; Interest. If any Rent or other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of ten (10) days after receipt of written notice, such sum shall bear a late charge equal to one percent (1.0%) of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

 

23


17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise (excluding, however, specific performance against the Tenant) and the exercise or beginning of the exercise by the Parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by United States registered or certified mail, return receipt and signature requested, postage prepaid, to the Parties at the following numbers and addresses:

 

To the Tenant:    Venture Global Calcasieu Pass, LLC
   c/o Venture Global LNG, Inc.
   1001 19th Street North
   Suite 1500
   Arlington, VA 22209
   Attention: General Counsel
   Telephone: [***]
   Email: [***]

With a copy to:

   [***]
   Norman Business Law Center
   145 East Street
   Lake Charles, LA 70601
   Telephone: [***]
   Email: [***]
To the Landlord:    Henry Venture, LLC
   2837 West Sale Road
   Lake Charles, LA 70605
   Attention: [***]
   Telephone: [***]
   Facsimile:
   Email: [***]

 

24


With a copy to:    Stockwell, Sievert, Viccellio, Clements &
   Shaddock, LLP
   P.O. Box 2900
   Lake Charles, LA 70602-2900
   Attention: [***]
   Email: [***]

or to such other numbers or addresses as either above designated recipients may from time to time designate by written notice to the other designated recipient hereto at least fifteen (15) days in advance of an effective date stated therein.

18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mail, return receipt and signature requested, postage prepaid.

19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable possession of the Project Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Project Site during the Initial Term, any Extended Term and any Removal Period of this Ground Lease without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord. This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow compatible use of the remainder of their property adjacent to the Project Site and will not create or allow the creation of a visual, olfactory or auditory nuisance on said remainder of their property.

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that: (i) it is the sole owner of good title to all of the Project Site; (ii) the Project Site is subject to no Liens, privileges, encumbrances, defects in title, servitudes, easements, restrictions, dedications, leases, mineral leases, reservations or other exceptions to title; (iii) during the term hereof it shall not encumber the Project Site; (iv) it is authorized to make this Ground Lease for the term hereof; (v) the provisions of this Ground Lease do not and will not conflict with or violate any of the provisions of existing agreements between the Landlord and any third party; and (vi) the Landlord will deliver the Project Site free of all tenants and occupants and claims thereto. The Landlord has furnished to the Tenant’s counsel a complete and up-to-date abstract of title at the Landlord’s sole expense, prior to the execution of this Ground Lease.

 

25


20. Eminent Domain.

20.1 Complete Condemnation. If, during the term hereof, the whole of the Project Site shall be taken under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking) by any public or private authority, then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided that the Tenant shall share in the condemnation award as provided herein. The Tenant may continue to occupy the Project Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Project Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Project Site from and after the date of such taking.

20.2 Partial Condemnation. If, during the term hereof, any public or private authority shall, under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking), makes a taking resulting in the reduction of the surface area of the Project Site by fifteen percent (15%) or more, or of fifteen percent (15%) or more of the value of the Facility, the Improvements or the Landlord’s Improvements, or resulting in material interference to the Project or the Tenant’s ability to use in a commercially reasonable manner the remainder of the Project Site, the Facility, the Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of the exercise of its election within one-hundred twenty (120) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2, the term hereof shall cease and terminate as of the last day of the calendar month in which such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant, and the Tenant shall share in the condemnation award as provided herein.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the term hereof shall continue in full force and effect, and the Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete taking pursuant to Section 20.1, the Tenant will be entitled to receive the portion of the condemnation award (or settlement) attributable to (i) the value of the Facility and Improvements and Landlord’s Improvements, and fixtures and other property located on the Project Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Project Site so taken, plus (iii) other compensation or benefits paid as a consequence of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking (if any such compensation or benefits are paid by the applicable taking authority) and the Landlord shall be entitled to recover that portion of the condemnation award (or settlement) fairly attributable to the value of the land taken. In the event Tenant’s Property, the Improvements or the Facility are not taken, the Tenant shall not be entitled to any portion of the award, and in the event none of the Landlord’s Property

 

26


is taken, the Landlord shall not be entitled to any portion of the award, unless the Tenant elects to terminate this Ground Lease pursuant to Section 20.2, in which event the award or settlement shall be allocated as provided in the next sentence. In the event of a partial taking of the Improvements, Tenant’s Property and/or the Facility not resulting in a termination of this Ground Lease pursuant to Section 20.2, the entire award or settlement shall be paid to the Tenant. In the event of a partial taking of the Project Site, the Tenant will be entitled to receive the portion of the award attributable to (i) the value of the portion of the Facility, Improvements and Tenant’s Property located in the portion of the Project Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Project Site so taken, plus (iii) damage to the remaining Facility, and the Tenant will promptly restore the remaining portion of the Facility to the extent of the award payable to the Tenant. Nothing contained herein shall prohibit the Tenant’s claiming relocation damages or damages for lost profits or loss of leasehold advantage against the taking authority in any appropriate proceeding.

21. Temporary Taking or Other Deprivation.

If, during the term hereof, (i) less than all of the Landlord’s title to all or any portion of the Project Site is taken for temporary use or occupancy, or (ii) any public or private authority takes any action not resulting in a taking of all or any portion of the Project Site but resulting in a right to compensation therefor, such as changing of the grade of any street upon which the Project Site abuts, then, except as otherwise provided in Section 20, the Tenant shall be entitled to make claim for, recover, and retain all awards, whether pursuant to judgment, agreement, or otherwise, recoverable in connection therewith.

22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure; provided that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section shall govern and control.

 

27


23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Project Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage, or any agent or trustee therefor, that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant. The term “Leasehold Mortgage” shall mean, at any point in time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Project Site and this Ground Lease. It is acknowledged and agreed that, during the term of this Ground Lease, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the term of this Ground Lease, the Tenant shall provide the Landlord with written notice of the identity, contact information and address for each Leasehold Lender, such notice to be provided to the Landlord by the Tenant within no less than a calendar year within which the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

23.2 Right to Perform for Tenant; Right to Cure.

(a) In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and the Landlord shall accept such performance by Leasehold Lender with the same force and effect as if furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing.

(b) If any default in the performance of an obligation of the Tenant under this Ground Lease is not susceptible to being cured by Leasehold Lender, the Landlord shall have no right to terminate this Ground Lease with respect to such default and such default shall be deemed waived for the benefit of Leasehold Lender only; provided that:

(i) Leasehold Lender shall have commenced to cure (i) any other non-payment default of the Tenant that is susceptible to being cured by Leasehold Lender and (ii) any default in the payment of any portion of Rent, in each case, within the time periods prescribed under Section 23.2(a);

(ii) Leasehold Lender (or its designee) shall have commenced to acquire the Tenant’s interest in this Ground Lease and the Project Site or to commence foreclosure or other appropriate proceedings under the Leasehold Mortgage within the time periods prescribed under Section 23.2(a);

 

28


(iii) if Leasehold Lender (or its designee) shall acquire the Tenant’s interest in this Ground Lease and/or the Project Site, Leasehold Lender (or its designee) shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition; and

(iv) if any third party shall, by foreclosure or dation en paiement under the Leasehold Mortgage or by assignment or other transfer from Leasehold Lender, acquire the Tenant’s interest in and to the Project Site under this Ground Lease, such third party shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by a third party with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition.

However, if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then notwithstanding any provision in this Section 23 to the contrary, the Landlord may exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’s prior written consent, and any such action taken without Leasehold Lender’s consent shall not be binding on the Tenant or Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.4 Delivery of Notices. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including, without limitation, any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been delivered to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in

 

29


writing to the Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Project Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’s interests in the Project Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including, without limitation, the acquisition of the Tenant’s interest in this Ground Lease and the Project Site created thereby in a transaction described in this Section 23 or the taking of possession of the Project Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender, provided that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Project Site.

23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2, the purchaser at any sale of this Ground Lease and the interests in and to the Project Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including, without limitation, power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Project Site thereby created under any instrument of assignment or transfer in lieu of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Project Site thereby created.

 

30


23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, substantially all, or any part of the Project Site or the Tenant’s Facility. Rent shall continue to be due and payable as set forth in this Ground Lease.

23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent domain proceeding of all, substantially all, or any part of the Project Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Facility, the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Project Site created by this Ground Lease and the value of the leasehold improvements located on the Project Site, up to an amount equaling the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Facility and/or the Tenant’s interest in, under and to this Ground Lease; provided that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under applicable law to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this Ground Lease. In the event of a taking of a portion of the Project Site, the Rent shall be reduced pro rata based upon the portion of the Project Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease.

23.9 New Direct Lease.

(a) If this Ground Lease is canceled or terminated for any reason (except in connection with a Bankruptcy Proceeding, for which the provisions of Section 23.10 are hereby agreed upon by the Landlord and the Tenant), and provided that Leasehold Lender has (i) commenced to cure and continues diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, and (ii) cured any payment default in respect of any portion of Rent, the Landlord hereby agrees that the Landlord shall, upon Leasehold Lender’s written election within one hundred twenty (120) days of such cancellation or termination, promptly enter in a new, direct lease with Leasehold Lender (or its nominee or any other party which Leasehold Lender may designate, including without limitation, the Tenant) with respect to the Project Site on the same terms and conditions as this Ground Lease (a “New Lease”), it being the intention of the parties to preserve this Ground Lease and the interests in and to the Project Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Said New Lease shall be superior to all rights, liens and interests intervening between the date of this Ground Lease and the granting of the New Lease and shall be free of any and all rights of the Tenant under this Ground Lease.

 

31


(b) The Tenant and the Landlord acknowledge and agree that Leasehold Lender shall have the right to encumber such direct New Lease and the estate created thereby with a deed of trust or a mortgage (as the case may be) on the same terms and with the same lien priority as the Leasehold Mortgage, it being the intention of the parties to preserve the priority of the Leasehold Mortgage, this Ground Lease and the interests in and to the Project Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. If this Ground Lease is rejected, cancelled or terminated for any reason and Leasehold Lender, its nominee or a designee of Leasehold Lender enters into a direct lease with the Landlord with respect to the Project Site, the Landlord hereby agrees that it will execute such documents as Leasehold Lender may require in order to ensure that the new direct lease provides for customary leasehold mortgagee protections, including without limitation, protections similar to those contained herein.

23.10 Bankruptcy. In the event of a proceeding under the United States Bankruptcy Code (Title 11 U.S.C.) as now or hereafter in effect (a “Bankruptcy Proceeding”):

(a) If this Ground Lease is rejected in connection with a Bankruptcy Proceeding by the Tenant or a trustee in bankruptcy (or other party to such proceeding) for the Tenant, such rejection shall be deemed an assignment by the Tenant to the Leasehold Lender of the Tenant’s Property and all of the Tenant’s interest under this Ground Lease, and this Ground Lease shall not terminate and the Leasehold Lender shall have all rights and obligations of the Tenant as if such Bankruptcy Proceeding had not occurred, unless Leasehold Lender shall reject such deemed assignment by notice in writing to the Landlord within thirty (30) days following rejection of this Ground Lease by the Tenant or the Tenant’s trustee in bankruptcy. If any court of competent jurisdiction shall determine that this Ground Lease shall have been terminated notwithstanding the terms of the preceding sentence as a result of rejection by the Tenant or the trustee in connection with any such proceeding, the rights of Leasehold Lender to a New Lease from the Landlord pursuant to Section 23.9 hereof shall not be affected thereby.

(b) In the event of a Bankruptcy Proceeding against the Landlord:

(i) If the bankruptcy trustee, the Landlord (as debtor-in-possession) or any party to such Bankruptcy Proceeding seeks to reject this Ground Lease pursuant to United States Bankruptcy Code §365(h)(1), the Tenant shall not have the right to treat this Ground Lease as terminated except with the prior written consent of Leasehold Lender and the right to treat this Ground Lease as terminated in such event shall be deemed assigned to Leasehold Lender, whether or not specifically set forth in the Leasehold Mortgage, so that the concurrence in writing of the Tenant and the Leasehold Lender shall be required as a condition to treating this Ground Lease as terminated in connection with such Bankruptcy Proceeding.

 

32


(ii) Unless this Ground Lease is treated as terminated in accordance with Section 23.10(b)(i), then this Ground Lease shall continue in effect upon all the terms and conditions set forth herein, including Rent, but excluding requirements that are not then applicable or pertinent to the remainder of the term of this Ground Lease. Thereafter, the Tenant or its successors and assigns shall be entitled to any offsets against Rent payable hereunder for any damages arising from such bankruptcy, to the extent the Tenant’s operation of business has been materially interfered with, and any such offset properly made shall not be deemed a default under this Ground Lease. The lien of the Leasehold Mortgage shall extend to the continuing possessory rights of the Tenant following such rejection with the same priority as it would have enjoyed had such rejection not taken place.

23.11 Estoppel Certificates; Non-Disturbance Agreements.

(a) Upon Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel”) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under the Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant thereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that each of this Ground Lease and the Non-Disturbance Agreement, true, correct copies of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, have not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Project Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Landlord’s power and authority to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Project Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Project Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, and any Non-Disturbance Agreement, there do not exist any other agreements concerning the Project Site or this Ground Lease, whether oral or written, to which Landlord is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Project Site, other than those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the

 

33


Landlord Estoppel, the present lessor under this Ground Lease and owns good and indefeasible title to the Project Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Project Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Project Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Project Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (ix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

(b) Upon Leasehold Lender’s or the Landlord’s written request, the Tenant shall provide Leasehold Lender with an estoppel certificate (the “Tenant Estoppel”) which shall certify to such requesting Leasehold Lender (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Landlord of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Landlord of any other conditions required under this Ground Lease, (iii) as to any existing default of the Landlord under this Ground Lease, or alternatively that the Landlord is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Landlord hereunder, and as to any existing event or condition in existence as of the date of the Tenant Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Tenant to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Tenant, (v) that this Ground Lease, a true and correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Project Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Tenant’s power and authority to execute the Tenant Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Tenant asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Project Site, (x) as to any written notice received by the Tenant from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Project Site, (xi) that there are no fees, rents, royalties, or other sums, whether or not constituting rent, due and owing as of the date of the Tenant Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, there do not exist any other agreements concerning

 

34


the Project Site or this Ground Lease, whether oral or written, to which the Tenant is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Project Site, other than those set forth on a schedule to the Tenant Estoppel, (xiv) that the Tenant is, as of the date of the Tenant Estoppel, the present lessee under this Ground Lease and owns good and indefeasible title to the Project Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Tenant has not assigned, sublet, hypothecated, leased, or otherwise transferred it interests, or any portion thereof, in and to the Project Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Tenant’s interest in the Project Site, other than those set forth on a schedule to the Tenant Estoppel, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Tenant is a party or by which the Tenant is otherwise bound affecting the Tenant’s interest in and to the Project Site, (xvii) that the Tenant is not, as of the date of the Tenant Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Tenant has not commenced any action or sent any notice to the Landlord for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Tenant is not, as of the date of the Tenant Estoppel, entitled to terminate, cancel, modify, or surrender this Ground Lease, and (ix) as to such other matters related to this Ground Lease as such Leasehold Lender may reasonably determine from time to time.

(c) Upon Leasehold Lender’s or the Tenant’s written request, the Landlord shall enter into a non-disturbance agreement with Leasehold Lender or its designee, in the form attached hereto as Exhibit 5 (a “Non-Disturbance Agreement”).

23.12 No Termination by Confusion. There shall be no termination by confusion of this Ground Lease or any interest in this Ground Lease or of the interests in and to the Project Site created thereby, by reason of the fact that this Ground Lease or such interest therein may be directly or indirectly owned by any person who shall hold any ownership interest in the Project Site, nor shall there be such a termination by confusion by reason of the fact that all or any part of the interests in and to the Project Site created by this Ground Lease may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any ownership interest in the Project Site or any ownership interest of the Landlord under this Ground Lease.

23.13 Landlord’s Recognition of Tenant. The Landlord hereby recognizes the Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that the Tenant acquired its interest in this Ground Lease and in and to the Project Site in accordance with the terms of this Ground Lease.

23.14 Agreement to Amend. The Landlord recognizes the importance of the Tenant’s ability to obtain Leasehold Mortgages, and that the provisions of this Ground Lease may be subject to the approval of a Leasehold Lender. If any Leasehold Lender should require, as a condition to such financing, any reasonable modifications of this Ground Lease, whether for purposes of clarifying the provisions of this Ground Lease or to include provisions then customary for leasehold financing transactions, the Landlord agrees to execute the appropriate amendments to this Ground Lease; provided, however, that no such modification shall, to the detriment of the Landlord, impair any of the Landlord’s rights, as reasonably determined by the Landlord or increase any of the Landlord’s obligations, as reasonably determined by the Landlord, under this Ground Lease.

 

35


23.15 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

23.16 Subordination of Landlord’s Lien. The Landlord hereby subordinates any lien or privilege it may have on any movables found from time to time in or upon the Project Site, including without limitation, the Landlord’s privileges pursuant to La. Civil Code articles 2707, et seq., to any Leasehold Lender’s rights under this Section 23 and the lien of any Leasehold Mortgage.

23.17 No Waiver or Surrender. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Project Site and no agreement to accept a surrender of the Project Site shall be valid unless it is in writing and signed by the Landlord.

24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

24.2 Successors. The covenants, agreements, terms, provisions, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties hereto.

24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

 

36


24.6 No Oral Change or Termination. This Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties hereto with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

24.9 Litigation. In case of any litigation between the Parties hereto regarding the subject matter hereof, the losing Party shall pay all reasonable costs and expenses (including reasonable attorneys’ fees) of the prevailing Party. The venue of any litigation shall be solely in Calcasieu Parish.

24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

24.11 Authority. Each the Landlord and the Tenant represents and warrants that it has the authority to enter into this Ground Lease, that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date, (a) the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 3, evidencing its authority to execute and perform under this Ground Lease and (b) the Landlord shall deliver to the Tenant a resolution in the form attached hereto as Exhibit 4, evidencing its authority to execute and perform under this Ground Lease.

 

37


24.12 Brokers and/or Real Estate Agents. Each of the Landlord and the Tenant represents, acknowledges and agrees that it is not represented by any other real estate broker/agent and that, except as provided below, it is not responsible for payment of any other commissions to any real estate brokers/agents in connection with this Ground Lease. The Tenant agrees that it is responsible for payment of any and all commissions that may be due to Reinauer Real Estate Corporation pursuant to this Ground Lease.

24.13 Legal Relationships; Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. There is no third party beneficiary of this Ground Lease, except as provided in Section 23.15 and any rights of a Leasehold Lender as provided herein. This Ground Lease is the product of the Parties joint negotiation and equal drafting thereof. The language of this Ground Lease shall be construed as a whole according to its fair meaning and not construed strictly for or against any of the Parties pursuant to any statue, case law or rule of interpretation or construction to the contrary.

24.14 Settlement Funds. The Landlord and the Tenant acknowledge that the Landlord has a claim for property damages submitted to the Claims Administrator’s office of the BP Oil Spill/Deepwater Horizon Class Action Settlement, which allows for recovery of damages to coastal property. The recovery on any damage award from the Class Action Settlement is reserved solely for the benefit of the Landlord. The Landlord and the Tenant further agree that any similar claims, which may exist for damage to the Project Site, exclusive of any improvements of the Tenant, shall also be reserved to the sole benefit of the Landlord. Similar claims which may exist for damage to Tenant improvements and/or operations shall be reserved to the sole benefit of the Tenant.

24.15 Limited Recourse. The Landlord agrees that the sole recourse of the Landlord for any damages or liabilities due by the Tenant hereunder shall be limited to the assets of the Tenant, without recourse individually or collectively to the members or the Affiliates of the Tenant, the Financing Parties or their respective directors, officers, agents, members, shareholders, managers, partners, employees or representatives.

24.16 Memorandum of Lease. The Parties hereto agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’s interest hereunder; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease.

[Remainder of page left intentionally blank; signatures on following pages]

 

38


IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

    LANDLORD:

/s/ Chad Henry

   
WITNESS Chad Henry     HENRY VENTURE, LLC

/s/ Brenda Ulmer

    By:  

/s/ Ell Ray Henry

WITNESS Brenda Ulmer     Name:   Ell Ray Henry
    Title:   Manager

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Calcasieu and State of Louisiana, personally came and appeared Ell Ray Henry, who, after being sworn by me, did execute this agreement on the 8th day of March, 2019 at Lake Charles, State of Louisiana.

 

 

/s/ Alan McCall

 
  NOTARY PUBLIC  

 

    TENANT:

/s/ Ben Davidson

   
WITNESS Ben Davidson     VENTURE GLOBAL CALCASIEU PASS, LLC

/s/ Pauline Crane

   
WITNESS Pauline Crane     By:  

/s/ Keith Larson

    Name:   Keith Larson
    Title:   Secretary

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 11th day of March, 2019 at Arlington, State of Virginia.

 

 

/s/ Annette B. Thrasher

 
  NOTARY PUBLIC  

 

1


LIST OF EXHIBITS

 

Exhibit 1-A    Legal Description of Project Site
Exhibit 1-B    Project Site Survey Maps
Exhibit 2    Project and Facility Description
Exhibit 3    Tenant’s Resolution
Exhibit 4    Landlord’s Resolution
Exhibit 5    Form of Non-Disturbance Agreement

 

40


EXHIBIT 1-A

LEGAL DESCRIPTION OF THE PROJECT SITE

13 Acre Tract

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND A HALF INCH DIAMETER IRON PIPE; THENCE S.00°36’56”W., A DISTANCE OF 4,956.53 FEET TO A POINT ALONG THE EAST LINE OF SECTION 36, TOWNSHIP 15 SOUTH, RANGE 10 WEST; THENCE S.00°35’10”W., A DISTANCE OF 1,619.34 FEET ALONG THE EAST LINE OF SECTION 37, TOWNSHIP 15 SOUTH, RANGE 10 WEST TO A POINT BEING MARKED BY A FOUND 4” TRANSITE PIPE; THENCE N.89°24’41”W., A DISTANCE OF 1,321.14 FEET TO A POINT BEING MARKED BY A SET ONE AND A QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 885.47 FEET TO A POINT BEING MARKED BY A FOUND 1.25” DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 732.98 FEET TO A POINT BEING MARKED BY A FOUND 1.25” DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 676.76 FEET TO A POINT BEING MARKED BY A FOUND 1.25” DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 59.94 FEET TO A POINT BEING MARKED BY A FOUND 1.25” DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 284.89 FEET TO A POINT BEING MARKED BY A FOUND 1.25” DIAMETER IRON PIPE; THENCE S.89°27’01”E., A DISTANCE OF 201.04 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; SAID POINT BEING THE POINT OF BEGINNING; THENCE N.35°37’17”E., A DISTANCE OF 367.98 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE, OFFSET 63.02’ N.89°82’56”E OF TRUE POSITION; SAID POINT BEING THE POINT OF CURVE TO THE RIGHT HAVING A RADIUS OF 850.00 FEET AND A CENTRAL ANGLE OF 42°39’13”; THENCE NORTHEASTERLY ALONG THE ARC A DISTANCE OF 632.78 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE, OFFSET 63.02’ S.00°38’57”E. OF TRUE POSITION; THENCE N.78°16’30”E., A DISTANCE OF 402.91 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; THENCE S.00°36’56”W., A DISTANCE OF 728.99 FEET TO A POINT BEING MARKED BY A SET 1.25” DIAMETER IRON PIPE; THENCE N.89°27’01”W., A DISTANCE OF 1,119.26 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 569,028.55 SQUARE FEET OR 13.0631 ACRES, MORE OR LESS, IS SITUATED IN SECTIONS 36 & 37, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “D” ON THE HERE TO ATTACHED PLAT.

 

41


16 Acre Tract

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND A HALF INCH DIAMETER IRON PIPE; THENCE S.89°23’17”E., A DISTANCE OF 4,151.09 FEET TO POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.00°56’33”W., A DISTANCE OF 330.15 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; SAID POINT BEING THE POINT OF BEGINNING; THENCE S.00°56’33”W., A DISTANCE OF 759.51 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.01°19’17”W., A DISTANCE OF 84.97 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE N.72°05’45”W., A DISTANCE OF 1,018.37 FEET TO A NON TANGENT POINT OF CURVATURE BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE AND BEING ALONG THE EAST RIGHT-OF-WAY LINE OF PARISH ROAD NO. 3143; THENCE ALONG A CURVE TO THE LEFT A DISTANCE OF 94.75 FEET ALONG SAID RIGHT-OF-WAY TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; SAID NON TANGENT CURVE HAVING A RADIUS OF 830.00 FEET, A CENTRAL ANGLE OF 6°32’27”, AND CHORD OF N.20°24’44”E, 94.70 FEET; THENCE N.17°08’31”E., A DISTANCE OF 488.20 FEET ALONG SAID RIGHT-OF-LINE TO A POINT OF CURVATURE BEING MARKED BY SET 1.25 INCH DIAMETER IRON PIPE; THENCE ALONG A CURVE TO THE LEFT A DISTANCE OF 230.84 FEET ALONG SAID RIGHT-OF-WAY TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 630.00 FEET, A CENTRAL ANGLE OF 20°59’39”, AND CHORD OF N.06°38’41”E, 229.55 FEET; THENCE S.72°05’45”E., A DISTANCE OF 819.72 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 726,895.21 SQUARE FEET OR 16.6873 ACRES, IS SITUATED IN SECTIONS 6 & 7 TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “F2” ON THE HERE TO ATTACHED PLAT.

321 Acre Tract

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST, CAMERON PARISH, LOUISIANA, SAID POINT BEING MARKED BY A FOUND ONE AND A HALF INCH DIAMETER IRON PIPE; THENCE S.89°23’17”E., A DISTANCE OF 4,151.09 FEET TO POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.00°56’33”W., A DISTANCE OF 330.15 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.00°56’33”W., A DISTANCE OF 759.51 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.01°19’17”W., A DISTANCE OF 84.97 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; SAID POINT BEING THE POINT OF BEGINNING; THENCE S.01°19’50”W., A DISTANCE OF 814.24 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.00°59’32”W., A DISTANCE OF 785.80 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.00°58’57”W., A DISTANCE OF 930.52 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.01°11’40”W., A DISTANCE OF 776.09 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.00°39’53”W., A DISTANCE OF 565.19 FEET TO A

 

42


POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.01°11’52”W., A DISTANCE OF 440.92 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.00°22’57”W., A DISTANCE OF 423.69 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.01°08’07”W., A DISTANCE OF 990.50 FEET TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.00°27’34”W., A DISTANCE OF 103.48 FEET TO A POINT ALONG THE GLO MEANDER LINE BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.79°00’00”W., A DISTANCE OF 871.65 FEET ALONG SAID MEANDER LINE TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.80°00’00”W., A DISTANCE OF 930.60 FEET ALONG SAID MEANDER LINE TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE S.80°59’56”W., A DISTANCE OF 707.11 FEET ALONG SAID MEANDER LINE TO A POINT BEING MARKED BY A FOUND 1.25 INCH DIAMETER IRON PIPE; THENCE N.01°26’04”E., A DISTANCE OF 1,126.85 FEET TO A POINT BEING MARKED BY A FOUND 1.25 INCH DIAMETER IRON PIPE; THENCE N.01°26’04”E., A DISTANCE OF 1,126.85 FEET TO A POINT BEING MARKED BY A FOUND 1.25 INCH DIAMETER IRON PIPE; THENCE N.01°26’04”E., A DISTANCE OF 1,126.85 FEET TO A POINT BEING MARKED BY A FOUND 1.25 INCH DIAMETER IRON PIPE; THENCE N.01°13’11”E., A DISTANCE OF 1,487.61 FEET TO A NON TANGENT POINT OF CURVATURE BEING MARKED BY FOUND 1.25 INCH DIAMETER IRON PIPE AND BEING ALONG THE EAST RIGHT-OF-WAY LINE OF PARISH ROAD NO. 3143; THENCE ALONG A CURVE TO THE LEFT A DISTANCE OF 376.34 FEET ALONG SAID RIGHT-OF-WAY TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; SAID NON TANGENT CURVE HAVING A RADIUS OF 2,230.00 FEET, A CENTRAL ANGLE OF 09°40’10”, AND CHORD OF N.47°38’31”E, 375.89 FEET; THENCE N.42°48’26”E., A DISTANCE OF 542.03 FEET ALONG SAID RIGHT-OF-WAY TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE N.42°32’07”E., A DISTANCE OF 731.72 FEET ALONG SAID RIGHT-OF-LINE TO A POINT OF CURVATURE BEING MARKED BY SET 1.25 INCH DIAMETER IRON PIPE; THENCE ALONG A CURVE TO THE LEFT A DISTANCE OF 390.53 FEET ALONG SAID RIGHT-OF-WAY TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 1,830.00 FEET, A CENTRAL ANGLE OF 12°13’18”, AND CHORD OF N.36°25’18”E, 389.79 FEET; THENCE N.30°18’29”E., A DISTANCE OF 144.89 FEET ALONG SAID RIGHT-OF-WAY LINE TO A POINT OF CURVATURE BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; THENCE ALONG A CURVE TO THE LEFT DISTANCE OF 95.98 FEET ALONG SAID RIGHT-OF-WAY TO A POINT BEING MARKED BY A SET 1.25 INCH DIAMETER IRON PIPE; SAID CURVE HAVING A RADIUS OF 830.00 FEET, A CENTRAL ANGLE OF 06°37’32”, AND CHORD OF N.26°59’43”E, 95.93 FEET; THENCE S.72°05’45”E., A DISTANCE OF 1,018.37 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 14,014,076.58 SQUARE FEET OR 321.7189 ACRES, IS SITUATED IN SECTIONS 5,6, & 7 TOWNSHIP 15 SOUTH, RANGE 9 WEST, CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS PARCEL “E” ON THE HERE TO ATTACHED PLAT.

 

43


EXHIBIT 1-B

SURVEY MAP OF PROJECT SITE

[Omitted]


EXHIBIT 2

PROJECT AND FACILITY DESCRIPTION

[Omitted]


EXHIBIT 3

TENANT’S RESOLUTION

[Omitted]


EXHIBIT 4

LANDLORD’S RESOLUTION

[Omitted]


EXHIBIT 5

FORM OF NON-DISTURBANCE AGREEMENT

[Omitted]

Exhibit 10.63

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

STATE OF LOUISIANA

PARISH OF CAMERON

GROUND LEASE AGREEMENT

(60 Acres)

This GROUND LEASE AGREEMENT (this “Ground Lease”) is executed and effective as of December 12, 2023 (the “Ground Lease Commencement Date”), by and between Venture Global CP2 LNG, LLC, a Delaware limited liability company (the “Tenant”) and JADP Venture, LLC, a Louisiana limited liability company (the “Landlord”). Each of the Tenant and the Landlord is referred to in this Ground Lease as “Party” and are both referred to as the “Parties.”

WITNESSETH:

WHEREAS, the Landlord is the owner of certain immovable (real) property including improved and unimproved land and certain water and surface and subsurface land rights situated in Cameron Parish, Louisiana, which comprises approximately sixty (60) acres identified herein as the Project Site as further defined below; and

WHEREAS, the Tenant is desirous of leasing land owned by the Landlord for the construction and development and operation of a natural gas liquefaction facility as generally described in Exhibit 2 (the “Facility”) and other uses permitted by this Ground Lease; and

WHEREAS, the Landlord and the Tenant desire to lease such land in order to develop the land with the Facility and thereby create and provide employment opportunities for the inhabitants of Southwest Louisiana, which will add to the welfare and prosperity of the persons residing within the geographic limits of numerous surrounding Parishes and throughout the State of Louisiana; and

WHEREAS, in accordance with the above, the Tenant has executed this Ground Lease and offers fair value to the Landlord as cause and consideration for this Ground Lease; and

NOW, THEREFORE, in consideration of the above recitals and the mutual covenants hereinafter contained, these recitals are made an integral part of this Ground Lease, and the Parties herein covenant and agree as follows:

1. Definitions.

As used in this Ground Lease, the following terms shall have the respective meanings indicated below:

Adjustment Period” has the meaning set forth in Section 4.1(c).


 

Affiliate” means any Person controlled by, controlling or under common control with the Landlord or the Tenant, as applicable. The words “control”, “controlled” and “controlling” mean ownership, directly or indirectly, of thirty percent (30%) or more of the legal or beneficial ownership interest of such Person or the power to direct or cause the direction of the management and policies of any such Person.

Applicable Laws” means all present and future laws, ordinances, orders, rules and regulations of all federal, state, parish, and municipal governments, departments, commissions, or offices, in each case having applicable jurisdiction over the Project Site.

Bankruptcy Proceeding” has the meaning set forth in Section 23.10.

Bona Fide Offer” means a bona fide written offer to purchase all or any portion of the Project Site from a true, independent third party, who is not an Affiliate of the Landlord and who is otherwise making the offer in good faith and on an arms-length basis that the Landlord desires to accept.

Business Day” means a day other than a Saturday, Sunday or any other day on which banking institutions in the state of New York are authorized or required by law to close.

Consumer Price Index” has the meaning set forth in Section 4.2.

Corps” has the meaning set forth in Section 8.2(a).

Corrective Measures” has the meaning set forth in Section 9.4(b).

CPI Adjustment” has the meaning set forth in Section 4.1.

CPI Disagreement Notice” has the meaning set forth in Section 4.2.

CPI Notice” has the meaning set forth in Section 4.2.

CPI Percentage Increase” has the meaning set forth in Section 4.2.

Environmental Laws” means any and all federal, state and local laws, statutes, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law or similar provisions having the force or effect of law, concerning pollution or protection of health, safety, natural resources or the environment or relating to land use, plants or animals or protected resources and any Applicable Law relating to natural resources, threatened or endangered species, migratory birds or disposal or wetlands and includes Hazardous Substances Law.

Event of Default” has the meaning set forth in Section 15.1.

Extended Term” has the meaning set forth in Section 3.2(a).

 

2


 

Facility” has the meaning set forth in the Recitals hereof.

Facility Contractors” means, collectively, the Persons engaged by the Tenant to construct the Facility and/or develop the Project, Project Site and/or Improvements.

Facility Contracts” means, collectively, the contracts entered into by the Tenant in connection with the design, construction, equipment procurement, operation and maintenance of the Facility and/or the Project, Project Site and/or Improvements.

Financing Parties” means the lenders, security holders, investors, export credit agencies, multilateral institutions, equity providers and others providing debt or equity financing or refinancing to, or on behalf of, the Tenant, or any Affiliate of the Tenant, for the development, construction, ownership, operation or maintenance of the Project or any portion thereof, or any trustee or agent acting on behalf of any of the foregoing, including Leasehold Lenders.

Force Majeure” means any cause not reasonably within the control of the Party claiming suspension, and shall include, but not be limited to, the following: (i) physical events such as acts of God, landslides, lightning, earthquakes, fires, storms or storm warnings, such as hurricanes, which result in evacuation of the affected area, droughts, floods, washouts, explosions, breakage or accident or necessity of repairs to machinery or equipment or lines of pipe; (ii) weather related events affecting an entire geographic region; (iii) acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, terrorism, discovery of burial grounds or human remains or legally protected artifacts, insurrections or wars; (iv) the failure or interruption of performance by the Tenant’s engineering, procurement and construction contractor or any subcontractors of such contractor to the extent caused by an event of Force Majeure under this Ground Lease; (v) the failure or interruption of performance by the Tenant’s suppliers by reason of such supplier’s valid declaration of an event that would constitute an event of force majeure under the Tenant’s contract with such supplier; (vi) governmental actions such as necessity for compliance with any court order, law, statute, ordinance, regulation, or policy having the effect of law promulgated by a Governmental Authority having jurisdiction, or that restrict the Tenant’s ability to reasonably construct and/or operate the Facility and/or Project or any delay in issuance or effectiveness of any Governmental Approval that has been properly applied for by the Tenant that is required to construct and/or operate the Facility and/or Project.

Governmental Approval” means any authorization, waiver, consent, approval, license, lease, franchise, ruling, permit, tariff, rate, right of way, certification, exemption, filing, variance, claim, order, judgment, decree, publication, notices to, declarations of or with or registration by or with any Governmental Authority.

Governmental Authority” means any nation or government, any state or political subdivision thereof, any federal, state, municipal, local, territorial or other governmental department, commission, board, bureau, agency, regulatory authority, instrumentality, judicial or administrative body, domestic or foreign, and any Person exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government.

Ground Lease” has the meaning set forth in the Preamble hereof.

 

3


 

Ground Lease Commencement Date” has the meaning set forth in the Preamble hereof.

Hazardous Substance” means (i) any chemical, compound, material, mixture or substance that is now or hereafter defined or listed in, or otherwise classified pursuant to, any Environmental Law as a “hazardous substance,” “hazardous material,” “hazardous waste,” “extremely hazardous waste,” “acutely hazardous waste,” “restricted hazardous waste,” “radioactive waste,” “infectious waste,” “biohazardous waste,” “toxic substance,” “pollutant,” “toxic pollutant,” “contaminant” or any other formulation not mentioned herein intended to define, list, or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity, toxicity, reproductive toxicity, “EP toxicity” or “TCLP toxicity”; (ii) petroleum, natural gas, natural gas liquids, liquefied natural gas, synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas) and ash produced by a resource recovery facility utilizing a municipal solid waste stream, and drilling fluids, produced waters and other wastes associated with the exploration, development or production of crude oil, natural gas, or geothermal resources; (iii) any flammable substances or explosives; (iv) any radioactive materials; (v) any pesticide; (vi) asbestos in any form; (vii) urea formaldehyde foam insulation; (viii) transformers or other equipment which contain dielectric fluid containing levels of polychlorinated biphenyls (PCBs) in excess of fifty (50) parts per million; (ix) radon; and (x) any other chemical, material, or substance that, because of its quantity, concentration, or physical or chemical characteristics, exposure to which is regulated for health and safety reasons by any Governmental Authority, or which is or has been demonstrated to pose a significant present or potential hazard to human health and safety or to the environment if released into the workplace or the environment.

Hazardous Substances Law” means the published cleanup standards of any Governmental Authority with jurisdiction over the Project Site and any and all federal, state and local statutes, laws, regulations, ordinances, judgments, orders, codes, injunctions, applicable common law, Applicable Law and similar provisions having the force or effect of law concerning the generation, distribution, use, treatment, storage, disposal, arrangement for disposal, cleanup, transport or handling of Hazardous Substances including, but not limited to, the Federal Water Pollution Control Act (as amended), the Resource Conservation and Recovery Act of 1976 (as amended), the Comprehensive Environmental Response, Compensation and Liability Act of 1980 (as amended), the Toxic Substances Control Act (as amended) and the Occupational Safety and Health Act of 1970 (as amended) to the extent they relate to the handling of and exposure to Hazardous Substances.

Improvements” means any and all improvements made by Tenant, in its sole discretion, to the Project Site, including but not limited to, improvements relating to the loading, unloading, handling, treatment, processing, producing, transporting, distributing, selling, metering and/or storing of (i) natural gas, natural gas liquids, and other natural gas products, derivatives and by-products and (ii) other petroleum and hydrocarbon liquids, gases, products, derivatives and by-products, including but not limited to (A) the importation, regasification, production, exportation, liquefaction, refinement, enhancement, other treatment and transportation (including by ship, pipeline, truck or rail) of LNG, and LNG by-products and additives and (B) the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of any improvements, component parts and other

 

4


 

constructions, fixtures, facilities, equipment and/or appurtenances (including natural gas pipelines, natural gas liquids extraction, processing and delivery facilities, acid gas removal units, natural gas liquefaction trains, LNG regasification facilities, and other treatment facilities, cryogenic pipelines, LNG storage tanks, petroleum and other hydrocarbon liquids storage facilities, nitrogen storage and processing facilities, power generation and transmission infrastructure, marine, rail and trucking receipt, delivery and servicing facilities (including piers, marine terminals, bulkheads, wharfs, docks, inlets, wetslips, moonpools, moorings, jetties, and loading and unloading equipment), and other utilities and facilities (including berms, open space, security fencing, control rooms, offices, warehouses, parking and yards), in each case, necessary, ancillary or desirable to the Tenant in connection with the foregoing.

Initial Term” has the meaning set forth in Section 3.1.

Landlord” has the meaning set forth in the Preamble hereof.

Landlord Estoppel” has the meaning set forth in Section 23.11(a).

Landlord’s Activities” means the action or failure to act of the Landlord or any of its representatives, affiliates, invitees, agents, advisors, consultants, contractors, or other Persons acting by or through the Landlord, at and/or relating to the Project Site and/or Landlord’s Improvements.

Landlord’s Event of Default” has the meaning set forth in Section 16.1.

Landlord Indemnitee” has the meaning set forth in Section 9.1.

Landlord’s Improvements” has the meaning set forth in Section 6.1.

Lease Year” means a period of twelve (12) consecutive full calendar months. The first Lease Year shall begin on the Ground Lease Commencement Date. Each succeeding Lease Year shall commence upon the anniversary of the first day of the previous Lease Year.

Leasehold Lenders” has the meaning set forth in Section 23.1.

Leasehold Loan” has the meaning set forth in Section 23.1.

Leasehold Mortgage” has the meaning set forth in Section 23.1.

Lien” means, with respect to any asset, any mortgage, deed of trust, lien, pledge, charge, security interest, restrictive covenant, easement, servitude or encumbrance of any kind in respect of such asset, whether or not filed, recorded or otherwise perfected or effective under Applicable Laws, as well as the interest of a vendor or lessor under any conditional sale agreement, capital lease or other title retention agreement relating to such asset.

LNG” means liquefied natural gas.

 

5


 

Minerals” has the meaning set forth in Section 8.2(b).

New Lease” has the meaning set forth in Section 23.9(a).

Non-Disturbance Agreement” has the meaning set forth in Section 23.11(c).

Party” or “Parties” has the meaning set forth in the Preamble hereof.

Person” means and includes natural persons, corporations, limited liability companies, general partnerships, limited partnerships, joint stock companies, joint ventures, associations, companies, trusts, banks, trust companies, land trusts, business trusts, or other organizations, whether or not legal entities, and governments and agencies and political subdivisions thereof.

Project” means the development, permitting, financing, construction, ownership, operation and/or maintenance of the Facility and the Improvements on the Project Site.

Project Site” means the real (immovable) property of approximately sixty (60) acres described in the legal description set forth in Exhibit 1-A and illustrated by the Survey Map attached as Exhibit 1-B, including any waterway areas, upon which the Facility and other Improvements will be located and which real (immovable) property is owned by the Landlord.

Property Taxes” means all real (immovable) and personal (movable) property taxes and all excise taxes of all Governmental Authorities, excluding any taxes, fees and/or levies associated with any mineral rights and/or royalties.

Removal Period” means the one thousand two hundred fifty (1250) day period that is required by Tenant to remove any and all of Tenant’s Property, including the Facility and/or Improvements, from the Project Site in accordance with Section 7.1.

Rent” has the meaning set forth in Section 4.1.

Surface Waiver” has the meaning set forth in Section 8.2(b).

Survey Map” means the ALTA survey of the Project Site, dated October 2, 2023 by Lonnie G. Harper & Associates, Inc., attached as Exhibit 1-B.

Tenant” has the meaning set forth in the Preamble hereof.

Tenant Estoppel” has the meaning set forth in Section 23.11(b).

Tenant Indemnitee” has the meaning set forth in Section 9.3.

 

6


 

Tenant’s Property” means all improvements, additions, replacements, enhancements, alterations, machinery, equipment, spares, furniture, furnishings, component parts and other constructions, inventory and other property and fixtures of any kind and at any time made, installed, fixed, or placed on, in, or to the Project Site by or on behalf of Tenant, including the Facility and any Improvements.

Tower Lease” has the meaning set forth in Section 2.2.

2. Ground Lease Premises.

2.1 Date. The date of this Ground Lease is the Ground Lease Commencement Date.

2.2 Landlord’s Agreement to Lease. Upon the terms and conditions hereinafter set forth, and in consideration of the payment of the rents and subject to the prompt performance by the Tenant of the covenants and agreements to be kept and performed by the Tenant under this Ground Lease, the Landlord does lease to the Tenant and the Tenant hereby leases from the Landlord, the Project Site and Landlord’s Improvements subject to that certain Contract of Lease, by and between W.F. Henry, Jr., as trustee of the James Austin and Martha Davis Trust for Lonnie A. Davis, the James Austin and Martha Davis Trust for Wilma Davis Guthrie, and the James Austin and Martha Davis Trust for Mary Davis Henry and Carmen V. Gebhardt, Linda D. Dlouhy, Mary P. Davis Lakhdari and George A. Davis, as lessor, and American Tower, L.P. (successor in interest to Allied Tower Rentals, Inc.), as lessee, dated March 31, 1972, filed April 4, 1972, recorded under Clerk’s File No. 128954, in Conveyance Book 290, Page 330, and filed December 29, 1987, recorded under Clerk’s File No. 207239, in Conveyance Book 659, Page 168, as affected by that certain Assignment filed December 29, 1987, recorded under Clerk’s File No. 207243, in Conveyance Book 659, Page 192; as affected by that Lease Extension filed July 9, 1992, recorded under Clerk’s File No. 227748, in Conveyance Book 752, Page 332, as affected by that certain Extended Lease Agreement filed February 26, 1993, recorded under Clerk’s File No. 230176, in Conveyance Book 764, Page 750, as affected by that certain Addendum to Land Lease Agreement At Cameron #1 filed October 13, 1998, recorded under Clerk’s File No. 257320, in Conveyance Book 886, Page 323, as affected by that certain First Amendment to Lease dated February 23, 2006 as evidenced by that certain Memorandum of Lease filed May 16, 2006, recorded under Clerk’s File No. 297896, of the records of Cameron Parish, Louisiana, for so long as such Tower Lease remains in full force and effect.

2.3 Servitudes. In addition, the Landlord or its Affiliates, as applicable, shall without cost to the Tenant, grant from time to time to the Tenant and others designated by the Tenant any easements, servitudes, and rights of way for access and electricity, communications, gas, water, sewer, and other utility lines, products and materials from and to the Project Site over land and waterways that are adjacent to the Project Site and controlled by the Landlord or its Affiliates, sufficient to permit the Tenant to accomplish its purposes in connection with the Project.

3. Term

3.1 Initial Term. The initial term of this Ground Lease shall commence at 12:01 a.m. on the Ground Lease Commencement Date and, unless sooner terminated as hereinafter provided, end at 11:59 p.m. on the thirtieth (30th) anniversary of the last day of the month immediately preceding the Ground Lease Commencement Date (the “Initial Term”).

 

7


 

3.2 Extensions.

(a) In consideration of and conditioned upon there being no uncured Event of Default on the part of the Tenant at the time an option is exercised, the Landlord hereby grants unto the Tenant the option to lease the Project Site for four (4) additional ten (10) year terms. If the extension option is exercised in accordance with Section 3.2(b), the first of said additional terms shall commence upon the expiration of the Initial Term and extend for a period of ten (10) years and each of said additional terms commencing upon the expiration of the then current additional term and extending for a period of ten (10) years. Each of such additional terms is referred to herein as an “Extended Term”.

(b) The option to extend this Ground Lease of the Project Site as set forth in Section 3.2(a) must be exercised in each case, if at all, by written notice from the Tenant to the Landlord on or before the date that is three (3) months prior to the expiration of the Initial Term or then current Extended Term, as applicable. The failure of the Tenant to timely exercise the first Extended Term or any subsequent Extended Term shall automatically terminate the right of the Tenant to exercise its option to lease the Project Site in any subsequent Extended Term.

(c) All the terms and conditions of this Ground Lease shall be applicable to any Extended Term and the Rent payable by the Tenant for any Extended Term shall be in accordance with the provisions set forth in Section 4.

4. Rent.

4.1 Rent. Commencing upon the Ground Lease Commencement Date, the initial rent for the Project Site (“Rent”) shall be [***] per annum, payable in equal installments of [***] per month, adjusted upward every five (5) years thereafter during the Initial Term and during any Extended Term by a percentage equal to the greater of [***] or the CPI Percentage Increase (as defined below), but in no event to exceed an adjustment during any Adjustment Period (as defined below) of greater than [***]. The period of time from the Ground Lease Commencement Date through March 14, 2024, and each five (5) year period thereafter shall be defined herein as an “Adjustment Period.” Any upward adjustment based on a CPI Percentage Increase (as defined below) to any payment under this Ground Lease shall hereinafter be referred to as a “CPI Adjustment.” Such Rent will be due each month on the 1st day of the month and shall be payable by the 15th day of that month; provided, however, that (i) the first payment of Rent shall be due on the Ground Lease Commencement Date and, if the Ground Lease Commencement Date is a date other than the first of the month, the first payment of Rent shall be in a prorated amount for the period of time between the Ground Lease Commencement Date and the next following first day of the month; and (ii) the first payment of Rent due upon the commencement of any new Adjustment Period will be owed and paid one month after the commencement of that Adjustment Period, in order to permit Tenant to calculate the CPI Percentage Increase, as set forth below.

 

8


 

4.2 CPI Adjustment. If CPI Percentage Increase (as defined below) is more than [***] for the relevant Adjustment Period, then the Rent payable during that Adjustment Period shall be adjusted upward by a percentage equal to the CPI Percentage Increase (as defined below) applicable to such Adjustment Period, but not to exceed an adjustment during any Adjustment Period of greater than [***]. The term “Consumer Price Index” shall mean the unadjusted Consumer Price Index for All Urban Workers, U.S. City Average, All Items, 1982-84=100, calculated and published by the United States Department of Labor, Bureau of Labor Statistics. The “CPI Percentage Increase” shall mean, with respect to any Adjustment Period, [***]. For the avoidance of doubt, no CPI Adjustment shall be made to any payment due under this Ground Lease for any Adjustment Period if the result of such CPI Adjustment would be to (a) reduce the amount of such payment to an amount that is less than the amount of such payment due for the immediately preceding Adjustment Period or (b) to raise the amount of such payment to an amount that is greater than [***]. For illustrative purposes only, [***]. The CPI Percentage Increase for any Adjustment Period shall be calculated by the Tenant, and the Tenant shall deliver written notice to the Landlord describing such calculation in reasonable detail (a “CPI Notice”) no later than thirty (30) days after the commencement of any Adjustment Period. If the Landlord disagrees with the Tenant’s calculation of the CPI Percentage Increase, then the Landlord shall deliver to the Tenant written notice, describing the basis for such disagreement in reasonable detail (a “CPI Disagreement Notice”), not later than thirty (30) days after delivery of the CPI Notice. If the Landlord fails to deliver a CPI Disagreement Notice within thirty (30) days after delivery of any CPI Notice, then the Landlord shall be conclusively deemed to have agreed with the calculation of the CPI Percentage Increase set forth in such CPI Notice.

4.3 Due Date. Except as otherwise provided in this Ground Lease, all Rent payments shall be due in advance on the 1st calendar day of each month and payable by the 15th calendar day of each month during the entire term of this Ground Lease. If the 15th calendar day of a month falls on a day that is not a Business Day, then Rent shall be payable on the following Business Day.

4.4 Place of Payment. Except as otherwise provided herein, Rent shall be payable by check or wire transfer at the address or via wire instructions as the Landlord may specify in writing to the Tenant and the Tenant deem acceptable, from time to time.

 

9


 

5. Net Lease; Taxes and Utility Expenses.

5.1 Net Lease. This Ground Lease is a net lease and it is agreed and intended that the Tenant shall pay or cause to be paid all operating costs, if any, of every kind and nature whatsoever relating to the Project Site except as expressly otherwise provided in this Ground Lease.

5.2 Taxes and Utility Expenses.

(a) The Tenant shall pay or cause to be paid when due all charges for water and sewer rents, public utilities, and Governmental Approval fees applicable to the Facility during the term of this Ground Lease.

(b) The Tenant shall pay or cause to be paid when due any and all Property Taxes on or related to the Project Site during the term of this Ground Lease. The Landlord shall promptly provide all Property Tax bills to the Tenant when they become available. Upon the latter of (i) one (1) month after receipt of such Property Tax bill from the Landlord or (ii) the due date of any such Property Taxes, the Tenant shall provide the Landlord with reasonable written evidence from the Cameron Parish Tax Collector’s Office of the payment of such taxes or provide notice of any election by the Tenant to contest the same in good faith; provided that the Tenant has entered into appropriate deposit, bond, or obtained an order of a court of competent jurisdiction, or other steps to appropriately stay any lien or collection efforts in connection with such contest.

5.3 Utility Connections. The Tenant shall be responsible for obtaining, at its own cost, electricity, telephone, water, sewerage, gas, and other utility services to the Project Site; provided, however, the Landlord shall cooperate and, to the extent reasonably needed, facilitate the contracting of any easements, servitudes and/or rights of way, and grant easements, servitudes and rights of way in accordance with Section 2.3, as required by the Tenant for such utility connections and/or services.

6. Tenant and Landlord Improvements.

6.1 Landlord’s Improvements.Landlord’s Improvements” are any and all improvements to the immovable property of the Project Site and any and all movable property in existence on the Project Site at the time of the Ground Lease Commencement Date. There are no Landlord’s Improvements.

6.2 Improvements by Tenant. The Tenant shall have the right to finance, construct, and install on the Project Site, the Facility and any Improvements during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. The Tenant shall be permitted to make any changes, improvements or alterations to the Project Site, including, without limitation, the Facility and any Improvements to the Project Site, during the Initial Term and/or any Extended Term as long as the changes, alterations and/or Improvements comply with Applicable Laws. During the term of this Ground Lease, the Tenant has the right to make any changes, alterations, and/or improvements with respect to the Project as long as such changes, alterations, and/or improvements comply with Applicable Laws.

 

10


 

6.3 Governmental Approvals. The Landlord will cooperate and assist (and never oppose) the Tenant in obtaining any and all Governmental Approvals deemed necessary by Tenant for the Facility and all other Improvements to the Project Site, including with respect to Governmental Approvals from the Federal Energy Regulatory Commission and the Department of Energy. The Landlord will hereafter continue to be obligated to execute appropriate documentation to waive its right to require wetlands mitigation to be completed on the Project Site or other real (immovable) property owned by the Landlord, in such form as necessary to allow the Tenant to complete such wetlands mitigation at locations other than other real (immovable) property owned by the Landlord.

6.4 Tenant’s Property. The Tenant’s Property shall at all times be and remain the sole property of the Tenant.

6.5 Maintenance of Improvements.

(a) Tenant’s Obligation to Maintain. During the Initial Term or any Extended Term, as applicable, the Tenant will keep in reasonably good state of repair the Facility, the Improvements, open areas, buildings, fixtures and building equipment that are brought or constructed or placed upon the Project Site by the Tenant, and the Tenant will, in its sole discretion and cost, repair such property as often as may be necessary in order to keep the Facility and Improvements in reasonably good repair and condition, except as set forth in Section 6.5(b).

(b) Landlord’s Obligation to Maintain. Except as otherwise provided in this Ground Lease, the Landlord has no obligation to maintain the Project Site, Improvements and/or Landlord’s Improvements (if any) during the Initial Term and/or any Extended Term. The Landlord further agrees that there will be no Landlord improvements on the Project Site on and after the Ground Lease Commencement Date.

6.6 Signs. The Tenant shall be permitted to place reasonable signs and other means of identification of its business on the Project Site so long as the same comply with all Applicable Laws and any required Governmental Approvals.

7. Tenant’s Surrender of Project Site.

7.1 Surrender at End of Ground Lease. Subject to Section 6.4 and subject and subordinate to Section 23 and the rights of any Leasehold Lender under any Leasehold Mortgage, the Tenant shall and will on the last day of the Initial Term, or if extended, on the last day of the Extended Term hereof, surrender and deliver the Project Site to the Landlord, in good condition as is reasonably practicable (except as provided in Section 6.5 or Section 13), excepting normal wear and tear. If this Ground Lease is terminated for any reason or upon the expiration of the Initial Term and/or Extended Term (if extended) of this Ground Lease, the Tenant shall in good faith proceed with (i) any removal of the Facility and any and all Improvements and (ii) restoration, if any, of the Project Site to its condition prior to construction of the Facility and/or Improvements, in accordance with Applicable Laws. During the Removal Period, the Tenant shall have all access rights to the Project Site that are necessary to remove any and all of Tenant’s Property, including the Facility and/or Improvements. The Tenant shall also comply as required by any federal regulations of the Federal Energy Regulatory Commission or any other federal authority with respect to the Facility on the Project Site.

 

11


 

7.2 Landlord Not Liable. On and after the Ground Lease Commencement Date the Tenant shall assume full dominion, control and responsibility for the Project Site, except to the extent specifically provided herein, to the extent provided under LSA – R.S. 9:3221. On and after the Ground Lease Commencement Date, the Landlord shall not be responsible for any loss or damage occurring to any real (immovable) or personal (movable) property owned, leased, or operated by the Tenant, its agents, or employees, prior to or subsequent to the termination of this Ground Lease, other than, to the extent permitted by law, for such loss or damage occurring as a result of the negligent conduct or the willful misconduct of the Landlord, its officers, representatives, agents, or employees or the Landlord’s misrepresentations or its breach of or default under this Ground Lease.

7.3 Holding Over. Except for the Removal Period, if the Tenant holds over after the expiration or termination of this Ground Lease, with or without the consent of the Landlord, such tenancy shall be from month-to-month only. Such month-to-month tenancy, whether with or without the Landlord’s consent, shall be subject to every other term, covenant, and agreement contained herein, and shall not constitute a renewal or extension of the term of this Ground Lease.

8. Use.

8.1 Permitted Uses; Compliance with Laws; Permits. The Tenant may use the Project Site for any and all uses desired by the Tenant in compliance with all Applicable Laws. The Tenant shall obtain and maintain, at its cost, all applicable Governmental Approvals for the construction and maintenance of the Facility, the Improvements and/or for the Tenant’s use or activities on the Project Site. The Tenant, at its cost, shall solely be responsible for complying with all Applicable Laws relative to the Project and security of the Project Site, including, but not limited to, the timely filing, implementation, and enforcement of any security plan required by Applicable Laws. Any fine or penalty imposed by any Governmental Authority solely caused by the failure of the Tenant to comply with this provision, including any fine or penalty imposed upon the Landlord as owner of the Project Site as solely caused by the failure of the Tenant to comply with this provision, shall be the sole responsibility of the Tenant, shall not be an Event of Default (as defined herein), and the Tenant shall indemnify and hold harmless the Landlord from the payment of any such fine or penalty, and the Tenant may pay any such fine or penalty, if any, to the Governmental Authority on behalf of the Landlord.

8.2 Dirt Moving Activities; Permits; Timber.

(a) The Tenant may remove, add and/or move substantial amounts of muck, dirt, dredge spoil, fill and other materials from the Project Site, to the Project Site, and from portions of the Project Site to other portions of the Project Site, and the Tenant may be required by Applicable Laws to mitigate wetlands on portions of the Project Site and may do so in its discretion. The Tenant shall have the right to remove soil and spoil from, and to add fill to, the Project Site and to dredge the slip and turning basin and dredge and widen the Calcasieu Ship Channel, and deposit the dredge spoils on the Project Site (as allowed by Applicable Law), in each case in connection with the excavation for, development, construction, installation, use, operation, maintenance, repair, expansion, optimization, alteration and/or removal of the Facility, and for the purpose of constructing, creating, expanding, operating and maintaining a marine terminal and

 

12


 

ship turning basin. The Tenant shall, at its own expense, obtain any required permits and/or approvals from the United States Army Corps of Engineers (the “Corps”) and/or any other governmental agencies, and the Tenant shall comply with such permits and approvals. The Landlord will cooperate with and assist the Tenant in obtaining any necessary permits and Governmental Approvals from the Corps and any other Governmental Authority, at the Tenant’s discretion, for the Tenant’s use of the Project Site, including without limitation, for any Improvements, reclamation of lands, erosion control, attainment of spoil, easements/servitudes and/or rights of way; provided that all costs associated with such efforts shall be the responsibility of the Tenant. Except only as provided in Section 8.2(b), the Tenant shall have all surface, subsurface and riparian rights, and the right and privilege of grading and draining the Project Site, and all other rights on and to the Project Site. Any activities of the Landlord and/or its lessees or assignees or any other party shall not adversely affect the Project Site or the Facility or interfere with the Tenant’s operations or rights under this Ground Lease in any way. Nothing herein is intended to preclude the Landlord, from participating in pools or units created by consent or established by any regulatory body including the Louisiana Commissioner of Conservation. The Tenant may freely remove any timber which is standing or lying on the Project Site as the Tenant deems necessary for the Tenant’s intended use of the Project Site. Nothing herein is intended to grant, convey, or bestow to the Tenant any rights to or claims to any oil, gas, or mineral rights below the surface of the Project Site.

(b) To the extent the Landlord holds any rights to oil, gas, or other minerals (“Minerals”) in the Project Site, Landlord waives any and all rights of the Landlord or its lessees or assignees to use the surface of the Project Site to explore for, drill for, access, extract, mine, exploit or otherwise make use of such Minerals, during the term of this Ground Lease, and the Landlord and/or its lessees or assigns shall only exercise any such rights to such Minerals via directional drilling or other means consistent with the terms and conditions of this Section 8.2(b) (“Surface Waiver”). If any third party holds any rights in such Minerals, the Landlord shall obtain a legal and binding written Surface Waiver from such third party, for the benefit of the Tenant and shall promptly provide a copy of such Surface Waiver to the Tenant. Any directional drilling or other subsurface Mineral activities of the Landlord and/or its lessees or assignees or any other party shall take place at a depth of not less than the greater of 2500 feet or such other depth as may be determined or set by the Federal Energy Regulatory Commission below the surface and shall not adversely affect the lateral or subjacent support of the Facility or interfere with the Tenant’s operations or rights under this Ground Lease in any way.

8.3 Crossing. The Landlord shall assist the Tenant in the Tenant’s efforts to develop, at the Tenant’s cost, any roads and/or crossings or other Improvements across the Project Site and boundary lines of the Project Site to the adjacent land, including relocation of utilities, providing culverts for storm water drainage, and any other Improvements. The Tenant or others, excluding the Landlord, will pay the cost to relocate or modify the infrastructure for these roads and/or crossings and/or other Improvements. The Landlord shall not be required to incur any costs or expenses in its efforts to assist the Tenant.

 

13


 

8.4 Pipelines; Rights of Way. If at any time the Tenant notifies the Landlord that the Project requires an off-Project Site pipeline and/or pipeline servitude for the development of the Project at the Project Site, the Landlord shall use its best efforts to cause the applicable landowners and Governmental Authorities to grant the pertinent approvals to achieve the pipeline and/or pipeline right of way. The Landlord shall not be required to incur any costs or expenses in its efforts to assist the Tenant.

9. Indemnification.

9.1 Tenant’s General Agreement to Indemnify. The Tenant releases the Landlord, its officers, representatives, employees, agents, successors and assigns (individually and collectively, the “Landlord Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Landlord Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, witness fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Landlord Indemnitee arising out of (i) the use or occupancy of the Project Site by the Tenant, its officers, representatives, agents, and employees, (ii) the construction or operation of the Project by the Tenant, its officers, representatives, agents, and employees, (iii) any claim arising out of the use, occupancy, construction or operation of the Project Site by the Tenant, its officers, representatives, agents, and employees, and (iv) activities on or about the Project Site by the Tenant, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with the construction, use, occupancy, operation, maintenance, or repair of the Facility, the Improvements, or the Project Site by the Tenant, its officers, representatives, agents, and employees; provided, however, that any such claim, liability, obligation, damage or penalty arising as a result of the negligence or willful misconduct of any Landlord Indemnitee shall be excluded from this indemnity. Any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Sections 9.2 and 9.4 and not this Section 9.1.

9.2 Tenant’s Environmental Indemnification. For purposes of the Tenant’s indemnification obligations, the Tenant agrees that it will comply with all Environmental Laws applicable to the Tenant, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Project Site. The Tenant agrees to indemnify and hold harmless the Landlord Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorney, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Landlord Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the Tenant’s breach of the covenant set forth above in this Section 9.2 or (ii) any discharge or release of Hazardous Substances on the Project Site or any violation of any Environmental Law with respect to the Project Site, in each case to the extent first occurring after the Ground Lease Commencement Date and caused by the Tenant’s construction, operations, and maintenance activities or facilities and not caused by the Landlord’s Activities or Landlord’s Improvements.

 

14


 

9.3 Landlord’s General Agreement to Indemnify. The Landlord releases the Tenant, its officers, representatives, employees, contractors, Financing Parties, agents, successors and assigns, (individually and collectively, the “Tenant Indemnitee”) from, assumes any and all liability for, and agrees to indemnify the Tenant Indemnitee against, all claims, liabilities, obligations, damages, penalties, litigation, costs, charges, and expenses (including, without limitation, reasonable attorney’s fees, engineers’ fees, architects’ fees, and the costs and expenses of appellate action, if any), imposed on, incurred by or asserted against any Tenant Indemnitee arising out of (i) the Landlord’s Activities or any use or occupancy of the Project Site by the Landlord, its officers, representatives, agents, and employees, (ii) any claim arising out of the use, occupancy, construction or operation of the Project Site by the Landlord, its officers, representatives, agents, and employees, and (iii) activities on or about the Project Site by the Landlord, its officers, representatives, agents, and employees, of any nature, whether foreseen or unforeseen, ordinary, or extraordinary, in connection with this Ground Lease; provided, however, that any such claim, liability, obligation, damage or penalty arising as a result of the negligence or willful misconduct of any Tenant Indemnitee shall be excluded from this indemnity. This Section 9.3 shall include within its scope but not be limited to any and all claims or actions for wrongful death, but any and all claims brought under the authority of or with respect to any Environmental Law or concerning environmental matters or Hazardous Substances shall be solely covered by Section 9.4 and not this Section 9.3.

9.4 Landlord’s Environmental Indemnification.

(a) For purposes of the Landlord’s indemnification obligations, the Landlord agrees that it will comply with all Environmental Laws applicable to the Landlord, including without limitation, those applicable to the use, storage, and handling of Hazardous Substances in, on, or about the Project Site. The Landlord agrees to indemnify and hold harmless the Tenant Indemnitee against and in respect of any and all damages, claims, losses, liabilities, and expenses (including, without limitation, reasonable attorneys, accounting, consulting, engineering, and other fees and expenses), which may be imposed upon, incurred by, or assessed against the Tenant Indemnitee by any other Person (including, without limitation, a Governmental Authority), arising out of, in connection with, or relating to the subject matter of: (i) the presence, discharge or release of Hazardous Substances, including all claims or alleged claims by any Governmental Authority or other Person for penalties, damages or injunctive relief or for the abatement of a nuisance related to the presence, discharge or release of Hazardous Substances, or (ii) any actual or alleged violation of Environmental Laws, in the case of each of subclauses (i) and (ii), where the presence, discharge or release of such Hazardous Substances or violation of Environmental Law arises or occurs (1) at, on or from the Project Site on or prior to the Ground Lease Commencement Date or (2) at, on or from the Project Site or any other site as a result of or relating to the Landlord’s Activities or facilities or Landlord’s Improvements, whether before, on or after the Ground Lease Commencement Date, or (iii) the Landlord’s breach of the covenant set forth above in this Section 9.4 or (iv) any environmental condition of contamination on the Project Site or any violation of any Environmental Law with respect to the Project Site to the extent occurring after the Ground Lease Commencement Date and caused by the Landlord’s Activities or facilities.

(b) If Hazardous Substances become present or are discharged onto the Project Site as a result of the Landlord’s Activities or otherwise exist at the Project Site on or prior to the Ground Lease Commencement Date, the Tenant shall so notify the Landlord in writing as soon as practicable after the Tenant’s discovery thereof. Except with respect to Hazardous Substances that become present or are discharged onto the Project Site as a result of the Landlord’s Activities, such

 

15


 

discovery and notice to the Landlord must occur within the Initial Term of this Ground Lease for the Landlord to have any obligation to perform any Corrective Measures (as hereinafter defined). Except as provided in the following sentence, upon receipt of such notice from the Tenant, the Landlord shall have a reasonable period of time to undertake, at its own expense, but subject to a limit of $5,000,000, such corrective measures as are necessary to remove such Hazardous Substances and to remediate such presence or discharge as required by applicable Environmental Laws or the requirements of the appropriate Governmental Authority (“Corrective Measures”), except that such Corrective Measures shall not unreasonably interfere with the construction, operation or maintenance of the Facility and/or interfere the Improvements by Tenant. At its discretion, upon written notice to the Landlord, the Tenant shall have the right to undertake such Corrective Measures and the Landlord shall reimburse the Tenant up to a total amount of $5,000,000 (or Tenant may offset against Rent) for its reasonable and necessary documented costs therefor within thirty (30) days after receipt of an invoice by the Landlord (including any costs associated with the work stoppage or interference with the ability of any Facility Contractor to perform its respective obligations under the Facility Contracts (including mobilization and de-mobilization costs, suspension costs, storage costs, rescheduling penalties, and all other direct and indirect costs incurred by the Tenant or any Facility Contractor (and its respective subcontractors) as a result of any delay caused by such Corrective Measures)). The Party not controlling the Corrective Measures under this Section 9.4(b) shall have a reasonable right of participation in the Corrective Measures, consisting of the right to (i) receive copies of material reports, work plans and correspondence relating to the Corrective Measures, (ii) the right to review and comment on draft reports and work plans (and all prompt and reasonable comments shall be considered and addressed by the controlling Party in good faith), and (iii) advance notice of and the right to attend and participate in meetings with Governmental Authorities. This Section 9.4(b) shall not supersede or diminish the provisions or the Landlord’s obligations under Section 9.4(a).

9.5 Survival of Indemnities. The foregoing indemnities shall survive the Initial Term, any Extended Term, and the Removal Period, and shall be in addition to any of the Landlord’s or the Tenant’s obligations for breach of a representation or warranty.

10. Insurance.

10.1 Tenant Insurance. Tenant shall carry or cause to be carried commercial general liability insurance with respect to the Project Site and the uses and activities of the Tenant thereon with minimum limits of [***]. The Tenant may elect to be self-insured in amounts greater than those minimum limits. In the event the Tenant procures commercial general liability insurance, the Landlord will be named as an additional insured.

10.2 Landlord Insurance. The Landlord may carry or cause to be carried relevant liability insurance with respect to the Project Site and/or any activities of the Landlord with respect to the Project Site in its reasonable business discretion. The Landlord may elect to be self-insured.

 

16


 

11. Liens and Landlord’s Mortgages.

11.1 Prohibition of Liens and Mortgages. The Landlord shall not create or permit to be created or to remain in connection with the Project Site, the Facility, the Improvements or the Landlord’s Improvements thereon, any Liens against any property interest of the Landlord and/or against any of Tenant’s Property or leasehold interest of the Tenant, and the Landlord or the Tenant (as applicable) shall discharge any Lien (levied on account of any mechanics’, laborers’, or materialmen’s lien or security agreement) which might be or become a Lien upon the Project Site or upon the Landlord’s interest in the Project Site or upon the Tenant’s interest in its leasehold of the Project Site, in accordance with Section 11.2.

11.2 Discharge of Liens.

(a) If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Project Site or any part thereof in connection with the Facility, the Improvements or the Landlord’s Improvements due to activities of the Landlord, the Landlord shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. If any mechanics’, laborers’, or materialmen’s lien shall at any time be filed against the Project Site or any part thereof in connection with the Facility, the Improvements or the Landlord’s Improvements due to activities of the Tenant, the Tenant shall be the responsible Party and shall within thirty (30) days after notice of the filing thereof, shall elect to contest the same or cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise.

(b) If the responsible Party does not contest such Lien and shall fail to cause such Lien to be discharged within the period aforesaid, then in addition to any other right or remedy of the non-responsible Party hereunder, the non-responsible Party may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such Lien by deposit or by bonding proceedings. Any amount so paid by the non-responsible Party and all costs and expenses incurred by the non-responsible Party in connection therewith, including reasonable attorneys’ fees together with interest thereon at one percent (1%) per annum above the Wall Street Journal Prime Rate of interest published from time to time in the Wall Street Journal, from the respective dates of the non-responsible Party’s making of the payment or incurring of the cost and expense, shall constitute either additional Rent payable by the Tenant under this Ground Lease or an offset against rent payable by the Tenant under this Ground Lease, and shall be either (as applicable) paid by the Tenant to the Landlord within fifteen (15) days of written demand therefor or offset against any Rent due after notice to the Landlord.

11.3 Satisfaction of Liabilities. The Tenant shall have the right but not the obligation to pay for the Landlord’s liabilities, obligations, responsibilities and/or debts associated with the Project Site, including without limitation, any liabilities, obligations and/or debts owed to laborers, vendors, brokers, materialmen, and other service providers, and then offset against the Rent any such amount(s) paid by the Tenant.

 

17


 

12. Entry on Premises by Landlord, Etc.

The Landlord and its representatives shall have no right to enter the Project Site, except as specifically authorized from time to time in advance in writing by the Tenant after written notice to Tenant of such request by the Landlord; and such authorization shall be in Tenant’s sole discretion, and if/when granted by the Tenant, the Landlord and its representatives shall be required to adhere to any confidentiality, health, safety, security, insurance and/or operating rules and procedures of Tenant. Such entry on the Project Site shall be accompanied by a Tenant representative at all times. If, for any reason, the Tenant deems it is unsafe or outside the bounds of contractual agreements for the Landlord to be near or within the bounds of certain operating equipment, the Tenant will instruct the Landlord of such safety or operating conditions such that access to certain sections of the Project Site will be restricted.

13. Destruction by Fire or Other Casualty.

If the Facility or any Improvements erected on the Project Site shall be destroyed or so damaged by fire or any other casualty whatsoever, not due to the willful misconduct of the Tenant, where repair or restoration cannot be reasonably accomplished within three hundred and sixty (360) days of the date of such fire or casualty, the Tenant, by written notice to the Landlord, from an authorized representative of the Tenant, may, at its election, decide not to restore nor reconstruct the Facility or the Improvements. In the event that the Tenant so decides not to restore or reconstruct the Facility or the Improvements, the Tenant shall notify the Landlord thereof in writing and shall proceed with due diligence to demolish and remove any ruins or rubble remaining on the Project Site at the Tenant’s sole cost and expense.

14. Assignment; Subleasing; Right of First Refusal.

14.1 Restrictions on Landlord. The Landlord shall not assign this Ground Lease or sell the Project Site, in whole or in part, (including without limitation by transfer of control or otherwise) without the prior written consent of the Tenant, which consent shall not be unreasonably withheld, delayed, or conditioned, except with respect to the Tenant’s right of first refusal as set forth in Section 14.3. This Ground Lease shall inure to the benefit of and shall be binding upon the Landlord’s permitted assigns.

14.2 Restrictions on Tenant. Subject to the provisions of Section 23, the Tenant shall not assign this Ground Lease, in whole or in part, without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned. The Tenant shall give the Landlord at least thirty (30) days prior written notice of any proposed assignment, together with a copy of the proposed assignment. In addition, the Landlord acknowledges and agrees that no approval or consent of the Landlord shall be required in connection with any assignment of this Ground Lease by the Tenant (i) for security purposes for any financing, including to a Leasehold Lender, (ii) to a Leasehold Lender or any purchaser upon a foreclosure of a Leasehold Mortgage or transferee upon a transfer in lieu of foreclosure (dation en paiement) pursuant to a Leasehold Mortgage, (iii) to any Affiliate or member of the Tenant, (iv) to any entity resulting from a merger, non-bankruptcy reorganization or consolidation with the Tenant, or (v) to any entity resulting from a merger or acquisition of the membership interest or assets of the Tenant so long as the surviving entity is fully responsible for all of the obligations of the Tenant hereunder. The Tenant shall not sublease all or any portion of the Project Site without the consent of the Landlord, which consent shall not be unreasonably withheld, delayed, or conditioned.

 

18


 

14.3 Right of First Refusal. During the Initial Term or any Extended Term of this Ground Lease, the Landlord may not transfer a portion of the Project Site and may only transfer the entire Project Site through a bona fide sale in exchange for a sum certain of money. If Landlord, during the Initial Term or any Extended Term of this Ground Lease, receives a Bona Fide Offer from a third party to buy or acquire all or any portion of the Project Site separately or as a part of a larger parcel of which the Project Site is a part, the Landlord will promptly, within ten (10) Business Days of such receipt, give written notice to Tenant of the terms of the Bona Fide Offer made or received, including the cash price attributable to the Project Site. If the sale is a tract of which the Project Site is a part, then the cash price attributable to the Project Site will be that part of the cash price multiplied times a fraction, the denominator of which is the total number of acres in the Project Site and the numerator of which is the total number of acres in the larger tract to be sold. The notice shall also state the other terms and conditions of the proposed sale and the Landlord’s willingness to sell for that cash price and on those terms. Upon receiving the notice, the Tenant may exercise the right, in the manner specified below, to purchase either the property described in the Bona Fide Offer or the Project Site (or part thereof) at the stated cash price in the Bona Fide Offer. This Section 14.3 does not apply to transfers pursuant to successions or donations executed in accordance with Louisiana law.

14.4 Exercise of Right of First Refusal. If the Tenant elects to purchase the property or Project Site described in the Bona Fide Offer under the provisions of Section 14.3, the Tenant must notify the Landlord of such election, doing so in writing delivered to the Landlord within thirty (30) Business Days after the date of the Landlord’s written notice to Tenant of the Bona Fide Offer. If the Tenant elects to refuse the Bona Fide Offer, the Tenant need take no action whatsoever; further, if the Tenant fails to deliver to the Landlord a notice of the Tenant’s election within the time required for such notice, the Tenant will be deemed to have refused the Bona Fide Offer. If the Tenant refuses, or is deemed to have refused, the Bona Fide Offer, the Landlord is free to sell the property pursuant to the Bona Fide Offer subject to this Ground Lease and any Leasehold Mortgage, any New Lease and any Non-Disturbance Agreement, and continuation of the leasehold interest created by this Ground Lease and any New Lease.

14.5 Continuation of Right. If for any reason the Project Site is not sold by the Landlord following a Bona Fide Offer from a third party, the right of first refusal granted and described in the preceding Sections 14.1 through 14.4 shall continue in full force and effect, on the same terms and conditions.

15. Events of Default of Tenant.

15.1 Event of Default. If any one or more of the following events shall happen and not be remedied as herein provided an “Event of Default” shall be deemed to have occurred:

(a) Breach of Rent Covenant. If the Tenant fails to timely pay Rent as provided in Section 4, and such failure shall continue for a period of fifteen (15) days after written notice thereof from the Landlord to the Tenant.

 

19


 

(b) Breach of Other Covenant. If default shall be made by the Tenant in the performance of or compliance with any of the covenants, agreements, terms, or conditions contained in this Ground Lease, other than those referred to in Section 15.1(a), and such default shall continue for a period of sixty (60) days after written notice thereof from the Landlord to the Tenant specifying the nature of such default and the acts required to cure the same, or, in the case of a default or a contingency which cannot with due diligence be cured within such period of sixty (60) days, the Tenant fails to proceed with due diligence within such period of sixty (60) days, to commence cure of the same and thereafter to prosecute the curing of such default with due diligence (it being intended that in connection with a default not susceptible of being cured with due diligence within sixty (60) days that the time of the Tenant within which to cure same shall be extended for such period as may be necessary to complete the same with all due diligence). Casualty occurring at the Project Site or discharge from the Project Site shall not constitute an Event of Default.

15.2 Landlord’s Remedies; Cure.

(a) Landlord’s Right to Damages; Termination. Subject to the rights and remedies of Leasehold Lender in Section 23, upon the occurrence of an Event of Default, the Landlord shall give written notice of Event of Default to the Tenant stating specifically the grounds for the Event of Default and the damages thereby reasonably anticipated or incurred by the Landlord in connection with the Event of Default, and the Tenant shall be liable for such reasonable damages unless such Event of Default is reasonably remedied in a timely manner and all undisputed arrears of Rent, and all other undisputed amounts payable by the Tenant under this Ground Lease, in each case within sixty (60) days from the date of such notice of Event of Default, together with interest thereon at the rate provided by law for judicial interest from the time when the same became due and payable, and all costs and expenses reasonably incurred by or on behalf of the Landlord as a result of the Event of Default, including reasonable attorneys’ fees, shall have been fully and promptly paid by the Tenant to the Landlord and all other defaults shall have been reasonably cured and made good or cured to the reasonable satisfaction of the Landlord, in either of which events the consequences of such Event of Default shall be deemed to be annulled. Written notice of an Event of Default under this Section 15.2(a) is not effective and is not valid if the Landlord does not give prior written notice to the Tenant pursuant to Section 15.1.

(b) Landlord’s Right to Cure Tenant’s Event of Default. Upon the occurrence of an Event of Default of the Tenant which is not cured or having commenced curing by the Tenant within sixty (60) days as provided in Section 15.2(b), then, subject to the prior written consent of any Leasehold Lender under Section 23, the Landlord may take whatever actions as are reasonably necessary to cure such Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others to cure the Event of Default. The Tenant shall be responsible for all costs, including attorney’s fees and the fees of other professionals, reasonably incurred by the Landlord pursuant to this Section 15.2(b) and such costs shall be billed to the Tenant in addition to any and all Rent due hereunder; and the Tenant shall pay all such additional costs and charges within thirty (30) days after billing by the Landlord.

15.3 Taking of Possession. Upon any expiration or termination of this Ground Lease, and subject to Section 7.1, (i) the Tenant shall quit and peacefully surrender the Project Site to the Landlord, without any payment therefor by the Landlord, and the Landlord may, at that time, without further notice, enter upon and re-enter the Project Site and may have, hold, and enjoy the Project Site; and (ii) all obligations of the Tenant hereunder for additional rent or any portion

 

20


 

thereof arising or accruing with respect to any period prior to such termination and any obligations of the Tenant under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof. In the event of any termination, the Landlord shall be under a duty to seek a successor tenant. If the Landlord obtains a successor tenant during what would have been the remainder of the term of this Ground Lease, the Tenant shall receive a credit for rentals collected from said successor tenant for the remaining term of this Ground Lease. If no successor tenant is obtained, the Tenant shall be liable for Rent obligations otherwise provided for in this Ground Lease.

15.4 Agent for Service. The Tenant shall maintain a registered agent of the Tenant for service of process, which agent will be located within the State of Louisiana. The Tenant shall maintain the name and address of such agent with the Louisiana Secretary of State. If the Tenant shall fail to maintain such a registered agent with the Louisiana Secretary of State within the State of Louisiana, service of process may be accomplished by public posting on the Project Site in the same manner and for the same period as provided in Louisiana statutes, with written notice becoming effective at the time of posting.

16. Events of Default of the Landlord.

16.1 Landlord’s Event of Default; Right to Cure. Any failure of the Landlord to perform and/or to comply with any of its obligations, covenants, agreements, terms, or conditions contained in this Ground Lease shall constitute a “Landlord’s Event of Default” hereunder. The Landlord shall have sixty (60) days after notice by the Tenant to the Landlord of Landlord’s Event of Default to fully cure Landlord’s Event of Default.

16.2 Tenant’s Remedies; Cure. In the event of a Landlord’s Event of Default that is not fully cured under Section 16.1, in addition to all other remedies available to the Tenant, the Tenant may cancel this Ground Lease by written notice to the Landlord. All obligations of the Landlord hereunder arising or accruing with respect to any period prior to such termination and any obligations of the Landlord under the indemnification provisions hereof arising or accruing with respect to any period prior to such termination hereof, in each case without regard to whether such matter is first noticed to the Landlord prior to or subsequent to such termination, shall survive the termination hereof, and shall be immediately payable to the Tenant. The Tenant shall have the right, with or without canceling this Ground Lease, to specific performance and to recover damages caused by a Landlord’s Event of Default that is not fully cured under Section 16.1.

16.3 Tenant’s Right to Cure Landlord’s Event of Default. Upon the occurrence of a Landlord’s Event of Default, the Tenant may take whatever actions as are reasonably necessary to cure such Landlord’s Event of Default, including the hiring of attorneys, contractors, consultants, architects, engineers, laborers, or others, purchasing the required goods or services and procuring necessary insurance. The Landlord shall be responsible for all costs including attorneys’ fees and the fees of other professionals, reasonably incurred by the Tenant pursuant to this Section 16.3 and such costs shall be billed to the Landlord. The Landlord shall pay all such additional costs and charges within thirty (30) days after billing by the Tenant, and/or the Tenant may offset such additional costs and charges against Rent due.

 

21


 

17. Mutual Obligations.

17.1 Late Charges; Interest. If any Rent or other sum is not paid when due and payable under this Ground Lease, and if such delinquency continues for a period of ten (10) days after receipt of written notice, such sum shall bear a late charge equal to one percent (1.0%) of the amount thereof, the Parties recognizing and agreeing that such charge represents a reasonable approximation of the additional administrative costs and expenses which are likely to be incurred by the non-defaulting Party. Additionally, any judgment rendered therefor shall bear interest from the date originally due to the date of collection at the rate prescribed by law as legal interest.

17.2 Obligations to Mitigate Damages. Both the Landlord and the Tenant shall have the obligation to take reasonable steps to mitigate their damages caused by any default under this Ground Lease.

17.3 Failure to Enforce Not a Waiver. No failure by either Party to insist upon the strict performance of any covenant, agreement, term, or condition of this Ground Lease or to exercise any right or remedy arising upon the breach thereof, and no acceptance by the Landlord of full or partial Rent during the continuance of any such breach, shall constitute a waiver of any such breach of such covenant, agreement, term, or condition. No covenant, agreement, term, or condition of this Ground Lease to be performed or complied with by either Party and no breach thereof shall be waived, altered, or modified except by a written instrument executed by both Parties. No waiver of any breach shall affect or alter this Ground Lease, but each and every covenant, agreement, term, or condition of this Ground Lease shall continue in full force and effect with respect to any other then existing or subsequent breach hereof.

17.4 Rights Cumulative. Except as provided herein, each right and remedy of the Parties provided in this Ground Lease shall be cumulative and shall be in addition to every other right or remedy provided for in this Ground Lease or now or thereafter existing at law or in equity or by statute or otherwise (excluding, however, specific performance against the Tenant) and the exercise or beginning of the exercise by the Parties of any one or more of such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Parties of any or all other such rights or remedies provided for in this Ground Lease or now or hereafter existing at law or in equity or by statute or otherwise.

18. Notices.

18.1 Addresses. All notices, demands, and requests which may or are required to be given hereunder shall be in writing, delivered by personal service, or shall be sent by United States registered or certified mail, return receipt and signature requested, postage prepaid, to the Parties at the following numbers and addresses:

 

22


 

To the Tenant:

  

Venture Global CP2 LNG, LLC

  

c/o Venture Global LNG, Inc.

1001 19th Street North

  

Suite 1500

  

Arlington, VA 22209

  

Attention: General Counsel

  

Telephone: [***]

  

Email: [***]

To the Landlord:

  

JADP Venture, LLC

  

602 West Prien Lake Road, #131

  

Lake Charles, LA 70601

  

Attention: [***]

  

Email: [***]

With a copy to:

  

Stockwell, Sievert, Viccellio, Clements &

  

Shaddock, LLP

  

P.O. Box 2900

  

Lake Charles, LA 70602-2900

  

Attention: [***]

  

Email: [***]

or to such other numbers or addresses as either above designated recipients may from time to time designate by written notice to the other designated recipient hereto at least fifteen (15) days in advance of an effective date stated therein.

18.2 When Deemed Delivered. Notices, demands, and requests which may or shall be served in accordance with Section 18.1 shall be deemed sufficiently served or given for all purposes hereunder at the earlier of (i) the time such notice, demand, or request shall be received by the addressee, or (ii) four (4) days after posting via United States registered or certified mail, return receipt and signature requested, postage prepaid.

19. Quiet Enjoyment; Title.

19.1 Quiet Enjoyment. The Landlord warrants to the Tenant the peaceable possession of the Project Site and warrants to the Tenant that the Tenant shall quietly have and enjoy the Project Site during the Initial Term, any Extended Term and the Removal Period of this Ground Lease without hindrance or molestation by the Landlord or any Person or Persons claiming by, under and/or through the Landlord. This Ground Lease shall be construed as a covenant running with the land. As long as this Ground Lease is in effect, the Landlord and any Affiliate of the Landlord shall only allow compatible use of the remainder of their property adjacent to the Project Site and, other than the existing sewage pond adjacent to the Project Site and the existing tower located on the Project Site pursuant to the terms of the Tower Lease, will not create or allow the creation of a visual, olfactory or auditory nuisance on said remainder of their property. Unless prior written consent is received from the Tenant, such consent not to be unreasonably withheld, the Landlord shall not cause the terms of the Tower Lease to be amended, modified, altered or changed in any respect.

 

23


 

19.2 Landlord’s Title. The Landlord covenants, represents and warrants as a condition of this Ground Lease that: (i) it is the sole owner of good title to all of the Project Site; (ii) the Project Site is subject to no Liens, privileges, encumbrances, defects in title, servitudes, easements, restrictions, dedications, leases, mineral leases, reservations or other exceptions to title; (iii) during the term hereof it shall not encumber the Project Site; (iv) it is authorized to make this Ground Lease for the term hereof; (v) the provisions of this Ground Lease do not and will not conflict with or violate any of the provisions of existing agreements between the Landlord and any third party; and (vi) the Landlord will deliver the Project Site free of all tenants and occupants and claims thereto.

20. Eminent Domain.

20.1 Complete Condemnation. If, during the term hereof, the whole of the Project Site shall be taken under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking) by any public or private authority, then this Ground Lease and the term hereof shall cease and terminate as of the date of such taking; provided that the Tenant shall share in the condemnation award as provided herein. The Tenant may continue to occupy the Project Site, subject to the terms of this Ground Lease, for all or such part of the period between the date of such taking and the date when possession of the Project Site shall be taken by the taking authority, and any unearned Rent or other charges, if any, paid in advance, shall be refunded to the Tenant. If required, the Tenant shall procure from the applicable Governmental Authority, at the Tenant’s sole cost and expense, all necessary consents and authorizations to continue to occupy the Project Site from and after the date of such taking.

20.2 Partial Condemnation. If, during the term hereof, any public or private authority shall, under the power of eminent domain (or in lieu of a taking by a person or entity authorized to exercise such power, condemnation or taking, or under threat of exercise of such power, condemnation or taking), makes a taking resulting in the reduction of the surface area of the Project Site by fifteen percent (15%) or more, or of fifteen percent (15%) or more of the value of the Facility, the Improvements or the Landlord’s Improvements, or resulting in material interference to the Project or the Tenant’s ability to use in a commercially reasonable manner the remainder of the Project Site, the Facility, the Improvements or Landlord’s Improvements for the purposes contemplated hereby, then the Tenant may, at its election, terminate this Ground Lease by giving the Landlord notice of the exercise of its election within one-hundred twenty (120) days of the date of notice to the Tenant of such taking. In the event of termination by the Tenant under this Section 20.2, the term hereof shall cease and terminate as of the last day of the calendar month in which such notice of exercise of its election to terminate has been given, and any unearned Rent or other charges, if any, paid in advance, shall not be refunded to the Tenant, and the Tenant shall share in the condemnation award as provided herein.

20.3 Rent Adjustment. In the event that the Tenant does not elect to terminate this Ground Lease pursuant to Section 20.2, then this Ground Lease and the term hereof shall continue in full force and effect, and the Rent shall be adjusted pro-rata in accordance with the land area of the property actually taken by the condemning authority.

 

24


 

20.4 Allocation of Award. Subject to Section 23.8, in the event of a complete taking pursuant to Section 20.1, the Tenant will be entitled to receive the portion of the condemnation award (or settlement) attributable to (i) the value of the Facility and Improvements and Landlord’s Improvements, and fixtures and other property located on the Project Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Project Site so taken, plus (iii) other compensation or benefits paid as a consequence of the interruption of the Tenant’s business and the other costs and expenses incurred by the Tenant as a consequence of such taking (if any such compensation or benefits are paid by the applicable taking authority) and the Landlord shall be entitled to recover that portion of the condemnation award (or settlement) fairly attributable to the value of the land taken. In the event Tenant’s Property, the Improvements or the Facility are not taken, the Tenant shall not be entitled to any portion of the award, and in the event no Landlord’s property is taken, the Landlord shall not be entitled to any portion of the award. In the event of a partial taking of the Improvements, Tenant’s Property and/or Facility, the entire award or settlement shall be paid to the Tenant. In the event of a partial taking of the Project Site, the Tenant will be entitled to receive the portion of the award attributable to (i) the value of the portion of the Facility, Improvements and Tenant’s Property located in the portion of the Project Site so taken, plus (ii) without duplication with clause (i) above, the value of the leasehold estate and leasehold advantage in the portion of the Project Site so taken, plus (iii) damage to the remaining Facility, and the Tenant will promptly restore the remaining portion of the Facility to the extent of the award payable to the Tenant. Nothing contained herein shall prohibit the Tenant’s claiming relocation damages or damages for lost profits or loss of leasehold advantage against the taking authority in any appropriate proceeding.

21. Temporary Taking or Other Deprivation.

If, during the term hereof, (i) less than all of the Landlord’s title to all or any portion of the Project Site is taken for temporary use or occupancy, or (ii) any public or private authority takes any action not resulting in a taking of all or any portion of the Project Site but resulting in a right to compensation therefor, such as changing of the grade of any street upon which the Project Site abuts, then, except as otherwise provided in Section 20, the Tenant shall be entitled to make claim for, recover, and retain all awards, whether pursuant to judgment, agreement, or otherwise, recoverable in connection therewith.

22. Force Majeure.

Provided that notice is given within sixty (60) days of an occurrence of an event of Force Majeure by the Party seeking to invoke and utilize the provisions of this Section 22, either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Ground Lease for so long as the performance of such obligations is prevented or significantly delayed, retarded or hindered by any event of Force Majeure; provided that an event of Force Majeure shall not excuse any party from making any payment of money required under this Ground Lease. Should an event of Force Majeure persist for over three hundred and sixty (360) continuous days, the Tenant shall have the right but not the obligation to terminate this Ground Lease.

23. Leasehold Mortgage Provisions.

The provisions of this Section 23 shall supersede any contrary or inconsistent provisions in this Ground Lease and in the event of any inconsistency or conflict between the provisions of this Section 23 and any other provision of this Ground Lease, the provisions of this Section shall govern and control.

 

25


 

23.1 Tenant’s Right to Mortgage Leasehold Interest; Recognition of Leasehold Lender as Leasehold Mortgagee. The Tenant shall have the absolute right (but not the obligation), without seeking the consent or approval of the Landlord, to grant one or more leasehold mortgages encumbering the Tenant’s interest in the Project Site and in this Ground Lease. The term “Leasehold Lender” shall mean, at any point in time, the holder of a Leasehold Mortgage, or any agent or trustee therefor, that provides written notice to the Landlord of its status as such, which notice is confirmed in writing by the Tenant. The term “Leasehold Mortgage” shall mean, at any point in time, a leasehold mortgage to secure debt or other equivalent instruments (“Leasehold Loan”) as the case may be (as the same may be amended from time to time), encumbering the Tenant’s interest in the Project Site and this Ground Lease. It is acknowledged and agreed that, during the term of this Ground Lease, there may be multiple Leasehold Mortgages and multiple Leasehold Lenders and that each Leasehold Lender may, from time to time, assign its right, title and interest in and to the Leasehold Loan, Leasehold Mortgage and this Ground Lease. During the term of this Ground Lease, the Tenant shall provide the Landlord with written notice of the identity, contact information and address for each Leasehold Lender (or the agent authorized to act on behalf of the Leasehold Lender), such notice to be provided to the Landlord by the Tenant within no less than a calendar year within which the Tenant becomes aware of any such Leasehold Lender, whether by the issuance of a Leasehold Mortgage to such Leasehold Lender or name change, assignment, merger or otherwise.

23.2 Right to Perform for Tenant; Right to Cure.

(a) In addition to the rights provided in Section 23.1, the Landlord acknowledges and agrees that any Leasehold Lender shall have the right to perform any term, covenant, condition or agreement to be performed by the Tenant under this Ground Lease, and Landlord shall accept such performance by Leasehold Lender with the same force and effect as if furnished by the Tenant. In the event of a default by the Tenant under this Ground Lease and prior to any termination of this Ground Lease by the Landlord, the Landlord acknowledges and agrees that the Landlord shall provide Leasehold Lender with notice of the same and Leasehold Lender shall have the right (but not the obligation) to commence to cure such default within the same period of time as the Tenant has under this Ground Lease, plus an additional sixty (60) days. The Landlord agrees that the Landlord shall not terminate this Ground Lease in connection with any such default so long as Leasehold Lender has cured or commenced to cure and continues diligently to cure in accordance with the foregoing.

(b) If any default in the performance of an obligation of the Tenant under this Ground Lease is not susceptible to being cured by Leasehold Lender, the Landlord shall have no right to terminate this Ground Lease with respect to such default and such default shall be deemed waived for the benefit of Leasehold Lender only; provided that:

(i) Leasehold Lender shall have commenced to cure (i) any other non-payment default of the Tenant that is susceptible to being cured by Leasehold Lender and (ii) any default in the payment of any portion of Rent, in each case, within the time periods prescribed under Section 23.2(a);

 

26


 

(ii) The Leasehold Lender (or its designee) shall have commenced to acquire the Tenant’s interest in this Ground Lease and the Project Site or to commence foreclosure or other appropriate proceedings under the Leasehold Mortgage within the time periods prescribed under Section 23.2(a);

(iii) if Leasehold Lender (or its designee) shall acquire the Tenant’s interest in this Ground Lease and/or the Project Site, Leasehold Lender (or its designee) shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition; and

(iv) if any third party shall, by foreclosure or dation en paiement under the Leasehold Mortgage or by assignment or other transfer from Leasehold Lender, acquire the Tenant’s interest in and to the Project Site under this Ground Lease, such third party shall, without prejudice to Section 23.5, (A) commence to cure and continue diligently to cure all non-payment defaults that are susceptible to being cured by a third party with commercially reasonable diligence, (B) cure any payment default in respect of any portion of Rent and (C) perform and observe all other agreements, covenants and conditions which are to be performed or observed by the Tenant under this Ground Lease after the date of such acquisition.

However, if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then notwithstanding any provision in this Section 23 to the contrary, the Landlord may exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.3 No Modification Without Leasehold Lender’s Consent. Neither the Landlord nor the Tenant will amend, modify, cancel or surrender this Ground Lease without Leasehold Lender’s prior written consent, and any such action taken without Leasehold Lender’s consent shall not be binding on the Tenant or Leasehold Lender or their respective successors and assigns (and this Ground Lease shall be interpreted as if such action was not taken); provided, however, that if the Tenant is in default beyond applicable notice and cure periods under this Ground Lease and Leasehold Lender fails to act under Section 23.2 within the applicable time periods set forth in Section 23.2, then Leasehold Lender’s prior written consent shall not be required for the Landlord to exercise any right to terminate this Ground Lease that the Landlord may have under Section 15.

23.4 Delivery of Notices. The Landlord shall simultaneously deliver to Leasehold Lender copies of all notices, statements, information and communications delivered or required to be delivered to the Tenant pursuant to this Ground Lease, including, without limitation, any notice of any default by the Tenant. In addition, the Landlord shall promptly notify Leasehold Lender in writing of any failure by the Tenant to perform any of the Tenant’s obligations under this Ground Lease. No notice, statement, information or communication given by the Landlord to the Tenant

 

27


 

shall be binding or affect the Tenant or Leasehold Lender or their respective successors and assigns unless a copy of the same shall have simultaneously been delivered to Leasehold Lender in accordance with this Section 23.4. All notices to Leasehold Lender shall be addressed to any Leasehold Lender at any address that such Leasehold Lender shall provide in writing to the Landlord and the Tenant, and shall be delivered in a manner permitted under (and shall be deemed delivered in accordance with) Section 18. Notwithstanding anything to the contrary in this Ground Lease, the Landlord shall not exercise any remedies related to the Tenant’s default hereunder until (i) the Landlord has delivered notice of such default to Leasehold Lender pursuant to this Section 23.4 and (ii) all applicable cure commencement periods following the delivery of such notice have expired.

23.5 Leasehold Lender Not Obligated Under Lease; Permitted Transfers. The granting of the Leasehold Mortgage shall not be deemed to constitute an assignment or transfer of this Ground Lease or the Project Site to Leasehold Lender, nor shall Leasehold Lender, in its capacity as the holder of the Leasehold Mortgage, be deemed to be an assignee or transferee of this Ground Lease or of the Tenant’s interests in the Project Site thereby created so as to require Leasehold Lender, as such, to assume the performance of any of the terms, covenants or conditions on the part of the Tenant to be performed thereunder. In no event shall any act or omission of Leasehold Lender (including, without limitation, the acquisition of the Tenant’s interest in this Ground Lease and the Project Site created thereby in a transaction described in this Section 23 or the taking of possession of the Project Site or improvements thereon through a receiver or other means) require Leasehold Lender to assume, or cause Leasehold Lender to be deemed to have assumed, any obligation or liability of the Tenant under this Ground Lease, and Leasehold Lender shall have no personal liability to the Landlord for the Tenant’s failure to so perform and observe any agreement, covenant or condition of the Tenant under this Ground Lease, it being expressly understood and agreed that, in the event of any such failure of the Tenant to perform, the Landlord’s sole and exclusive remedy with respect to Leasehold Lender shall be to terminate this Ground Lease without any recourse or claim for damages against Leasehold Lender; provided that this Section 23.5 shall not relieve Leasehold Lender of the requirements under Section 23.2(b)(iii) in the event that Leasehold Lender has elected to acquire the Tenant’s interests in this Ground Lease and/or the Project Site.

23.6 Permitted Transfers. Notwithstanding the provisions of Section 23.5, but for the avoidance of doubt while reserving the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2, the purchaser at any sale of this Ground Lease and the interests in and to the Project Site thereby created in any proceedings for the foreclosure of the Leasehold Mortgage (including, without limitation, power of sale), or the assignee or transferee of this Ground Lease and the interests in and to the Project Site thereby created under any instrument of assignment or transfer in lieu of the foreclosure (whether to Leasehold Lender or any third party) shall be deemed to be a permitted assignee or transferee under this Ground Lease without the need to obtain the Landlord’s consent and the Landlord shall recognize such assignee or transferee as the successor-in-interest to the Tenant for all purposes under this Ground Lease, and such purchaser, assignee or transferee shall be deemed to have agreed to perform all of the terms, covenants and conditions on the part of the Tenant to be performed under this Ground Lease from and after the date of such purchase and/or assignment, but only for so long as such purchaser or assignee is the owner of the Tenant’s interest in, to and under this Ground Lease and the Tenant’s interests in and to the Project Site thereby created.

 

28


 

23.7 No Termination for Casualty. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that this Ground Lease shall not terminate or be cancelled at any time upon the damage or destruction by fire or other casualty of all, substantially all, or any part of the Project Site or the Tenant’s Facility. Rent shall continue to be due and payable as set forth in this Ground Lease.

23.8 Expropriation and Expropriation Proceeds. So long as the indebtedness, or any part of the indebtedness, secured by the Leasehold Mortgage remains outstanding and unpaid, and the Leasehold Mortgage remains of record, the Landlord and the Tenant agree that: (i) this Ground Lease shall not terminate or be canceled upon a taking or expropriation pursuant to an eminent domain proceeding of all, substantially all, or any part of the Project Site without Leasehold Lender’s consent or unless required by law; (ii) any and all awards for any taking or expropriation of the Facility, the Improvements and/or the Tenant’s interest in, under and to this Ground Lease which otherwise belong to the Tenant shall be payable to Leasehold Lender, to be disbursed as follows: (A) first, to Leasehold Lender for the value of the interests in and to the Project Site created by this Ground Lease and the value of the leasehold improvements located on the Project Site, up to an amount equaling the outstanding principal balance of any loan secured by the Leasehold Mortgage, and any interest accrued thereon, and (B) second, to the Landlord and the Tenant in accordance with this Ground Lease; and (iii) Leasehold Lender shall have the right to apply the expropriation proceeds payable to Leasehold Lender hereunder in accordance with the terms of the Leasehold Mortgage (or other applicable loan documents) and shall be entitled at Leasehold Lender’s option to participate in any compromise, settlement or adjustment with respect to the claim for damages paid by the expropriating authority for the taking or expropriation of the Facility and/or the Tenant’s interest in, under and to this Ground Lease; provided that this Section 23.8 does not derogate the Landlord’s right to terminate this Ground Lease pursuant to Section 23.2. The Landlord reserves any rights it may have under applicable law to seek from the expropriating authority an award for a taking of the Landlord’s interests in, under and to this Ground Lease. In the event of a taking of a portion of the Project Site, the Rent shall be reduced pro rata based upon the portion of the Project Site taken. The Landlord agrees that, to the extent permitted by law, the Landlord waives and forebears the use of any of its power of expropriation that would impair the Tenant’s interest in, under and to this Ground Lease or the performance of this Ground Lease.

23.9 New Direct Lease.

(a) If this Ground Lease is canceled or terminated for any reason (except in connection with a Bankruptcy Proceeding, for which the provisions of Section 23.10 are hereby agreed upon by the Landlord and the Tenant), and provided that Leasehold Lender has (i) commenced to cure and continues diligently to cure all non-payment defaults that are susceptible to being cured by Leasehold Lender with commercially reasonable diligence, and (ii) cured any payment default in respect of any portion of Rent, the Landlord hereby agrees that the Landlord shall, upon Leasehold Lender’s written election within one hundred twenty (120) days of such cancellation or termination, promptly enter in a new, direct lease with Leasehold Lender (or its

 

29


 

nominee or any other party which Leasehold Lender may designate, including without limitation, the Tenant) with respect to the Project Site on the same terms and conditions as this Ground Lease (a “New Lease”), it being the intention of the parties to preserve this Ground Lease and the interests in and to the Project Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. Said New Lease shall be superior to all rights, liens and interests intervening between the date of this Ground Lease and the granting of the New Lease and shall be free of any and all rights of the Tenant under this Ground Lease.

(b) The Tenant and the Landlord acknowledge and agree that Leasehold Lender shall have the right to encumber such direct New Lease and the estate created thereby with a deed of trust or a mortgage (as the case may be) on the same terms and with the same lien priority as the Leasehold Mortgage, it being the intention of the parties to preserve the priority of the Leasehold Mortgage, this Ground Lease and the interests in and to the Project Site created by this Ground Lease for the benefit of Leasehold Lender without interruption. If this Ground Lease is rejected, cancelled or terminated for any reason and Leasehold Lender, its nominee or a designee of Leasehold Lender enters into a direct lease with the Landlord with respect to the Project Site, the Landlord hereby agrees that it will execute such documents as Leasehold Lender may require in order to ensure that the new direct lease provides for customary leasehold mortgagee protections, including without limitation, protections similar to those contained herein.

23.10 Bankruptcy. In the event of a proceeding under the United States Bankruptcy Code (Title 11 U.S.C.) as now or hereafter in effect (a “Bankruptcy Proceeding”):

(a) If this Ground Lease is rejected in connection with a Bankruptcy Proceeding by the Tenant or a trustee in bankruptcy (or other party to such proceeding) for the Tenant, such rejection shall be deemed an assignment by the Tenant to the Leasehold Lender of the Tenant’s Property and all of the Tenant’s interest under this Ground Lease, and this Ground Lease shall not terminate and the Leasehold Lender shall have all rights and obligations of the Tenant as if such Bankruptcy Proceeding had not occurred, unless Leasehold Lender shall reject such deemed assignment by notice in writing to the Landlord within thirty (30) days following rejection of this Ground Lease by the Tenant or the Tenant’s trustee in bankruptcy. If any court of competent jurisdiction shall determine that this Ground Lease shall have been terminated notwithstanding the terms of the preceding sentence as a result of rejection by the Tenant or the trustee in connection with any such proceeding, the rights of Leasehold Lender to a New Lease from the Landlord pursuant to Section 23.9 hereof shall not be affected thereby.

(b) In the event of a Bankruptcy Proceeding against the Landlord:

(i) If the bankruptcy trustee, the Landlord (as debtor-in-possession) or any party to such Bankruptcy Proceeding seeks to reject this Ground Lease pursuant to United States Bankruptcy Code §365(h)(1), the Tenant shall not have the right to treat this Ground Lease as terminated except with the prior written consent of Leasehold Lender and the right to treat this Ground Lease as terminated in such event shall be deemed assigned to Leasehold Lender, whether or not specifically set forth in the Leasehold Mortgage, so that the concurrence in writing of the Tenant and the Leasehold Lender shall be required as a condition to treating this Ground Lease as terminated in connection with such Bankruptcy Proceeding.

 

30


 

(ii) Unless this Ground Lease is treated as terminated in accordance with Section 23.10(b)(i), then this Ground Lease shall continue in effect upon all the terms and conditions set forth herein, including Rent, but excluding requirements that are not then applicable or pertinent to the remainder of the term of this Ground Lease. Thereafter, the Tenant or its successors and assigns shall be entitled to any offsets against Rent payable hereunder for any damages arising from such bankruptcy, to the extent the Tenant’s operation of business has been materially interfered with, and any such offset properly made shall not be deemed a default under this Ground Lease. The lien of the Leasehold Mortgage shall extend to the continuing possessory rights of the Tenant following such rejection with the same priority as it would have enjoyed had such rejection not taken place.

23.11 Estoppel Certificates; Non-Disturbance Agreements.

(a) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall provide Leasehold Lender or the Tenant with an estoppel certificate (the “Landlord Estoppel”) which shall certify to such requesting Leasehold Lender or the Tenant (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Tenant of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Tenant of any other conditions required under this Ground Lease, (iii) as to any existing default of the Tenant under this Ground Lease, or alternatively that the Tenant is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Tenant thereunder, and as to any existing event or condition in existence as of the date of the Landlord Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Landlord to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Landlord, (v) that each of this Ground Lease and the Non-Disturbance Agreement, true, correct copies of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, have not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Project Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Landlord’s power and authority to execute the Landlord Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Landlord asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Project Site, (x) as to any written notice received by the Landlord from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Project Site, (xi) that there are no fees, rents, royalties or other sums, whether or not constituting rent, due and owing as of the date of the Landlord Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, and any Non-Disturbance Agreement, there do not exist any other agreements concerning the Project Site or this Ground Lease, whether oral or

 

31


 

written, to which Landlord is a party, (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Project Site, other than those set forth on a schedule to the Landlord Estoppel, (xiv) that the Landlord is, as of the date of the Landlord Estoppel, the present lessor under this Ground Lease and owns good and indefeasible title to the Project Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Landlord has not assigned, sublet, hypothecated, leased, or otherwise transferred its interests, or any portion thereof, in and to the Project Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Landlord’s interest in the Project Site, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Landlord is a party or by which the Landlord is otherwise bound affecting the Landlord’s interest in and to the Project Site, (xvii) that the Landlord is not, as of the date of the Landlord Estoppel, holding a security deposit pursuant to the terms of this Ground Lease, (xviii) that the Landlord has not commenced any action or sent any notice to the Tenant for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Landlord is not, as of the date of the Landlord Estoppel, entitled to terminate, cancel, modify or surrender this Ground Lease, and (xix) as to such other matters related to this Ground Lease as Leasehold Lender may reasonably determine from time to time.

(b) Within fifteen (15) days following Leasehold Lender’s or the Landlord’s written request, the Tenant shall provide Leasehold Lender with an estoppel certificate (the “Tenant Estoppel”) which shall certify to such requesting Leasehold Lender (i) as to the amount and status of all rent payments under this Ground Lease, (ii) as to the non-satisfaction or non-compliance by the Landlord of any other conditions under this Ground Lease, or alternatively, as to the full satisfaction and compliance by the Landlord of any other conditions required under this Ground Lease, (iii) as to any existing default of the Landlord under this Ground Lease, or alternatively that the Landlord is not in default in the payment, performance or observance of any other condition or covenant to be performed or observed by the Landlord hereunder, and as to any existing event or condition in existence as of the date of the Tenant Estoppel which would, with passage of time or the giving of notice or both, constitute a default under this Ground Lease or otherwise entitle the Tenant to terminate, accelerate, or modify this Ground Lease or exercise any other remedy thereunder, or alternatively that no such event or condition exists, (iv) setting forth any offsets or counterclaims on the part of the Landlord or alternatively that there are no offsets or counterclaims on the part of the Tenant, (v) that this Ground Lease, a true and correct copy of which shall be attached thereto together with any amendments, modifications, assignments, restatements, and supplements thereof, has not, except to the extent set forth therein, been amended, modified, assigned, restated, supplemented, or waived in any respect whatsoever and collectively represent the entirety of the agreements between the Landlord and the Tenant with respect to the Project Site, (vi) as to the date on which the Initial Term or Extended Term, as applicable, is scheduled to expire, (vii) as to the Tenant’s power and authority to execute the Tenant Estoppel, (viii) as to any dispute, claim, or litigation (pending or threatened) regarding this Ground Lease or asserting that this Ground Lease is unenforceable, (ix) as to any notice given or received by the Tenant asserting that (A) this Ground Lease violates any agreement or applicable law or (B) any violations of any covenants, conditions, or restrictions of record affecting the Project Site, (x) as to any written notice received by the Tenant from any Governmental Authority respecting a condemnation or threatened condemnation of all or any portion of the Project Site, (xi) that there are no fees, rents, royalties, or other sums, whether or not constituting rent, due and owing as of

 

32


 

the date of the Tenant Estoppel and as to any Rent that the Tenant has prepaid under this Ground Lease, (xii) that, except this Ground Lease, there do not exist any other agreements concerning the Project Site or this Ground Lease, whether oral or written, to which the Tenant is a party (other than those set forth on a schedule to the Tenant Estoppel), (xiii) that there are no agreements, judgments, proceedings, liens, or encumbrances affecting the Project Site, other than those set forth on a schedule to the Tenant Estoppel, (xiv) that the Tenant is, as of the date of the Tenant Estoppel, the present lessee under this Ground Lease and holds a valid leasehold interest in the Project Site, subject to and as limited by encumbrances permitted under the Leasehold Mortgage, (xv) that the Tenant has not assigned, sublet, hypothecated, leased, or otherwise transferred it interests, or any portion thereof, in and to the Project Site, and has not agreed with any party or person to do so, and has not executed a mortgage, deed of trust, or other security instrument encumbering the Tenant’s interest in the Project Site, other than those set forth on a schedule to the Tenant Estoppel, (xvi) that there exist no options, rights of first refusal, or other similar rights or agreements to which the Tenant is a party or by which the Tenant is otherwise bound affecting the Tenant’s interest in and to the Project Site, (xvii) that the Tenant has not commenced any action or sent any notice to the Landlord for the purpose of exercising remedies or terminating, canceling, modifying, or surrendering this Ground Lease, and that the Tenant is not, as of the date of the Tenant Estoppel, entitled to terminate, cancel, modify, or surrender this Ground Lease, and (xviii) as to such other matters related to this Ground Lease as such Leasehold Lender may reasonably determine from time to time.

(c) Within fifteen (15) days following Leasehold Lender’s or the Tenant’s written request, the Landlord shall enter into a non-disturbance agreement with Leasehold Lender or its designee, in the form attached hereto as Exhibit 5 (a “Non-Disturbance Agreement”).

23.12 No Termination by Confusion. There shall be no termination by confusion of this Ground Lease or any interest in this Ground Lease or of the interests in and to the Project Site created thereby, by reason of the fact that this Ground Lease or such interest therein may be directly or indirectly owned by any person who shall hold any ownership interest in the Project Site, nor shall there be such a termination by confusion by reason of the fact that all or any part of the interests in and to the Project Site created by this Ground Lease may be conveyed or mortgaged in a leasehold mortgage, deed of trust, deed to secure debt or other equivalent instrument (as the case may be) to a mortgagee or beneficiary who shall hold any ownership interest in the Project Site or any ownership interest of the Landlord under this Ground Lease.

23.13 Landlord’s Recognition of Tenant. Landlord hereby recognizes Tenant as the current tenant party to this Ground Lease and acknowledges and agrees that Tenant acquired its interest in this Ground Lease and in and to the Project Site in accordance with the terms of this Ground Lease.

23.14 Agreement to Amend. The Landlord recognizes the importance of the Tenant’s ability to obtain Leasehold Mortgages, and that the provisions of this Ground Lease may be subject to the approval of a Leasehold Lender. If any Leasehold Lender should require, as a condition to such financing, any reasonable modifications of this Ground Lease, whether for purposes of clarifying the provisions of this Ground Lease or to include provisions then customary for leasehold financing transactions, the Landlord agrees to execute the appropriate amendments to this Ground Lease; provided, however, that no such modification shall, to the detriment of the Landlord, impair any of the Landlord’s rights, as reasonably determined by the Landlord or increase any of the Landlord’s obligations, as reasonably determined by the Landlord, under this Ground Lease.

 

33


 

23.15 Third-Party Beneficiary. Notwithstanding anything to the contrary in this Ground Lease, each Leasehold Lender shall be a third-party beneficiary solely and exclusively with respect to the provisions of this Section 23. There are no other third-party beneficiaries to this Ground Lease.

23.16 Subordination of Landlord’s Lien. The Landlord hereby subordinates any lien or privilege it may have on any movables found from time to time in or upon the Project Site, including without limitation, the Landlord’s privileges pursuant to La. Civil Code articles 2707, et seq., to any Leasehold Lender’s rights under this Section 23 and the lien of any Leasehold Mortgage.

24. Miscellaneous.

24.1 Time is of the Essence. Time is of the essence of each and all of the terms, conditions and provisions of this Ground Lease.

24.2 Successors. The covenants, agreements, terms, provisions, and conditions contained in this Ground Lease shall apply to and inure to the benefit of and be binding upon the Landlord and the Tenant and their permitted successors and assigns, except as expressly otherwise herein provided, and shall be deemed covenants running with the respective interests of the Parties hereto.

24.3 Surviving Covenants. Each provision of this Ground Lease which may require performance in any respect by or on behalf of either the Tenant or the Landlord after the expiration of the term hereof or its earlier termination shall survive such expiration or earlier termination.

24.4 Provisions Deemed Conditions and Covenants. All of the provisions of this Ground Lease shall be deemed and construed to be “conditions” and “covenants” as though the words specifically expressing or importing covenants and conditions were used to describe each separate provision hereof.

24.5 Headings. The headings and section captions in this Ground Lease are inserted only as a matter of convenience and for reference and in no way define, limit, or describe the scope or intent of this Ground Lease or in any way affect this Ground Lease as to matters of interpretation or otherwise. Unless the context shall otherwise require, references in this Ground Lease to sections, articles and exhibits shall mean and refer to sections, articles and exhibits, respectively, in this Ground Lease.

 

34


 

24.6 No Oral Change or Termination. This Ground Lease and the exhibits appended hereto and incorporated herein by reference contain the entire agreement between the Parties hereto with respect to the subject matter hereof, supersede any prior agreements or understandings between the Parties with respect to the subject matter hereof, including the Original Ground Lease, and no change, modification, or discharge hereof in whole or in part shall be effective unless such change, modification, or discharge is in writing and signed by the Party against whom enforcement of the change, modification, or discharge is sought. This Ground Lease cannot be changed or terminated orally.

24.7 Governing Law; Severability. This Ground Lease shall be governed by and construed in accordance with the laws of the State of Louisiana. If any term or provision of this Ground Lease or the application thereof to any Person or circumstance shall, to any extent, be held to be invalid or unenforceable, the remaining provisions of this Ground Lease or the application of such term or provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each term and provision of this Ground Lease shall be valid and enforceable to the fullest extent permitted by law.

24.8 Counterparts. This Ground Lease may be executed in one or more counterparts, each of which so executed shall be deemed to be an original and all of which together shall constitute but a single document. The Parties agree that the delivery of this Ground Lease may be effected by means of an exchange of facsimile or emailed signatures with original copies to follow by mail or courier service.

24.9 Litigation. In case of any litigation between the Parties hereto regarding the subject matter hereof, the losing Party shall pay all reasonable costs and expenses (including reasonable attorneys’ fees) of the prevailing Party. The venue of any litigation shall be solely in Cameron Parish.

24.10 Gender of Words. Words of any gender in this Ground Lease shall be held to include masculine or feminine and words denoting a singular number shall be held to include the plural, and plural shall include the singular, whenever the sense requires.

24.11 Authority. Each of the Landlord and the Tenant represents and warrants that it has the authority to enter into this Ground Lease, that, when executed, this Ground Lease shall be binding and enforceable in accordance with its terms. On the Ground Lease Commencement Date, (a) the Tenant shall deliver to the Landlord a resolution in the form attached hereto as Exhibit 3, evidencing its authority to execute and perform under this Ground Lease and (b) the Landlord shall deliver to the Tenant a resolution in the form attached hereto as Exhibit 4, evidencing its authority to execute and perform under this Ground Lease.

24.12 Brokers and/or Real Estate Agents. Each of the Landlord and the Tenant represents, acknowledges and agrees that it is not represented by any real estate broker/agent and that it is not responsible for payment of any other commissions to any real estate brokers/agents in connection with this Ground Lease.

24.13 Legal Relationships; Product of the Parties. This Ground Lease shall not be interpreted or construed as establishing a partnership or joint venture between the Landlord and the Tenant and neither Party shall have the right to make any representations or be liable for the debts or obligations of the other. There is no third party beneficiary of this Ground Lease, except as provided in Section 23.15 and any rights of a Leasehold Lender as provided herein. This Ground Lease is the product of the Parties joint negotiation and equal drafting thereof. The language of this Ground Lease shall be construed as a whole according to its fair meaning and not construed strictly for or against any of the Parties pursuant to any statue, case law or rule of interpretation or construction to the contrary.

 

35


 

24.14 Settlement Funds. The Landlord and the Tenant agree that any claims, which may exist for damage to the Project Site, exclusive of any improvements of the Tenant, shall be reserved to the sole benefit of the Landlord. Similar claims that may exist for damage to Tenant improvements and/or operations shall be reserved to the sole benefit of the Tenant.

24.15 Limited Recourse. The Landlord agrees that the sole recourse of the Landlord for any damages or liabilities due by the Tenant hereunder shall be limited to the assets of the Tenant, without recourse individually or collectively to the members or the Affiliates of the Tenant, the Leasehold Lenders or their respective directors, officers, agents, members, shareholders, managers, partners, employees or representatives.

24.16. Further Assurances. In connection with this Agreement and the transactions contemplated hereby, each Party shall execute and deliver any additional documents and instruments and perform any additional acts that may be necessary or appropriate to effectuate and perform the provisions of this Agreement and those transactions, including in connection with the requests of any Financing Parties or Leasehold Lender.

24.17 No Waiver or Surrender. Waiver by the Landlord of any right pertaining to any default of the Tenant shall not constitute a waiver of any right for either a subsequent default of the same obligation or any other default. No act or thing done by the Landlord or the Landlord’s agents shall be deemed to be acceptance of surrender of the Project Site and no agreement to accept a surrender of the Project Site shall be valid unless it is in writing and signed by the Landlord.

24.18 Memorandum of Lease. The Parties hereto agree to execute and cause to be properly recorded a memorandum of this Ground Lease, sufficient in form and content to give third parties constructive notice of the Tenant’s interest hereunder; and thus, any existing or hereafter filed liens, mortgages, conveyances, encumbrances, easements, and servitudes shall be subordinate to this Ground Lease.

[Remainder of page left intentionally blank; signatures on following pages]

 

36


 

IN WITNESS WHEREOF, the undersigned Parties have executed this Recognition and Non-Disturbance Agreement as of the date first above written.

 

/s/ Mary Ellen Henry

WITNESS Mary Ellen Henry

   

LANDLORD:

 

JADP VENTURE, LLC

/s/ Amy Singer

    By:  

/s/ E. Scott Henry

WITNESS Amy Singer     Name:   E. Scott Henry
    Title:   Manager

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Calcasieu and State of Louisiana, personally came and appeared E. Scott Henry, who, after being sworn by me, did execute this agreement on the 4th day of December, 2023 at Lake Charles, State of Louisiana.

 

/s/ Kathryn G. Matte

NOTARY PUBLIC

 

/s/ T.A.Wren

    TENANT:
WITNESS T.A. Wren    
    VENTURE GLOBAL CP2 LNG, LLC

/s/ Jeff Layman

    By:  

/s/ Keith Larson

WITNESS Jeff Layman     Name:   Keith Larson
    Title:   Secretary

SWORN TO AND SUBSCRIBED before me, the undersigned Notary Public, duly commissioned and qualified in and for the County/Parish of Arlington and State of Virginia, personally came and appeared Keith Larson, who, after being sworn by me, did execute this agreement on the 6th day of December, 2023 at Arlington, State of Virginia.

 

/s/ Michael Eliezer Millan

NOTARY PUBLIC

 

37


 

LIST OF EXHIBITS

 

Exhibit 1-A    Legal Description of Project Site
Exhibit 1-B    Project Site Survey
Exhibit 2    Project and Facility Description
Exhibit 3    Tenant’s Resolution
Exhibit 4    Landlord’s Resolution
Exhibit 5    Form of Non-Disturbance Agreement

 

38


 

EXHIBIT 1-A

LEGAL DESCRIPTION OF THE PROJECT SITE

PARCEL “C-2”

COMMENCING AT THE NORTHEAST CORNER OF IRREGULAR SECTION 35, TOWNSHIP 15 SOUTH, RANGE 10 WEST CAMERON PARISH, LOUISIANA; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.00°36’56”W., A DISTANCE OF 4,956.53 FEET TO A POINT ALONG THE EAST LINE OF IRREGULAR SECTION 36, TOWNSHIP 15 SOUTH, RANGE 10 WEST; THENCE S.00°35’10”W., A DISTANCE OF 1,619.34 FEET ALONG THE EAST LINE OF IRREGULAR SECTION 37; TOWNSHIP 15 SOUTH, RANGE 10 WEST TO A POINT; THENCE N.89°24’41”W., A DISTANCE OF 1,321.14 FEET TO A POINT; THENCE N.00°36’56”E., A DISTANCE OF 885.47 FEET TO A POINT; THENCE N.00°36’56”E., A DISTANCE OF 732.98 FEET TO A POINT; THENCE N.00°36’56”E., A DISTANCE OF 188.30 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 488.45 FEET TO A POINT; THENCE N.00°36’56”E., A DISTANCE OF 284.89 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°27’01”E., A DISTANCE OF 201.04 FEET TO A POINT; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE AND BEING THE POINT OF BEGINNING; THENCE S.89°27’01”E., A DISTANCE OF 1,119.26 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 728.99 FEET TO A POINT ALONG THE SOUTH RIGHT OF WAY LINE OF DAVIS ROAD; SAID POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 63.05’ S.00° 36’ 56”W. OF TRUE POSITION; THENCE N.78°16’30”E., A DISTANCE OF 668.32 FEET ALONG SAID RIGHT OF WAY TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE, OFFSET 49.96’ S.00° 12’ 05”W. OF TRUE POSITION; THENCE S.01°12’05”W., A DISTANCE OF 722.21 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.01°17’48”W., A DISTANCE OF 160.02 FEET TO A POINT BEING MARKED BY A FOUND FOUR INCH DIAMETER TRANSITE PIPE; THENCE S.32°00’12”E., A DISTANCE OF 170.32 FEET TO A POINT BEING MARKED BY A FOUND ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°20’36”E., A DISTANCE OF 950.02 FEET TO A POINT BEING MARKED BY A FOUND TWO INCH DIAMETER IRON PIPE; THENCE S.01°26’04”W., A DISTANCE OF 645.56 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°57’00”W., A DISTANCE OF 1,498.35 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE S.89°57’00”W., A DISTANCE OF 1,297.30 FEET TO A POINT BEING MARKED BY A SET ONE AND ONE QUARTER INCH DIAMETER IRON PIPE; THENCE N.00°36’56”E., A DISTANCE OF 831.17 FEET TO THE POINT OF BEGINNING.

SAID DESCRIBED PARCEL, CONTAINING 2,650,077.76 SQUARE FEET OR 60.8374 ACRES, IS SITUATED IN SECTIONS 36 & 37, TOWNSHIP 15 SOUTH, RANGE 10 WEST, AND SECTIONS 4 & 5, TOWNSHIP 15 SOUTH, RANGE 9 WEST. CAMERON PARISH, LOUISIANA AND IS MADE REFERENCE TO AS TRACT “C-2” ON THE HERETO ATTACHED PLAT. SAID PLAT PREPARED BY LONNIE G. HARPER & ASSOCIATES, BEARING LGH FILE NO. 09/7001/2023, AND DATED OCTOBER 2, 2023.

 

39


 

EXHIBIT 1-B

SURVEY MAP OF PROJECT SITE

[Omitted]


 

EXHIBIT 2

PROJECT AND FACILITY DESCRIPTION

[Omitted]


 

EXHIBIT 3

TENANT’S RESOLUTION

[Omitted]


 

EXHIBIT 4

LANDLORD’S RESOLUTION

[Omitted]


 

EXHIBIT 5

FORM OF NON-DISTURBANCE AGREEMENT

[Omitted]

Exhibit 10.64

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

LIMITED LIABILITY COMPANY AGREEMENT

among

CALCASIEU PASS FUNDING, LLC

and

THE MEMBERS NAMED HEREIN

dated as of

August 19, 2019


TABLE OF CONTENTS

 

              Page  

ARTICLE I. DEFINITIONS

     1  
 

Section 1.01

   Definitions      1  

  

 

Section 1.02

   Interpretation, Etc.      10  
 

Section 1.03

   Schedules      11  

ARTICLE II. ORGANIZATIONAL MATTERS

     11  
 

Section 2.01

   Formation      11  
 

Section 2.02

   Name      11  
 

Section 2.03

   Purpose      12  
 

Section 2.04

   Principal Place of Business; Foreign Qualifications      13  
 

Section 2.05

   Fiscal Year      13  
 

Section 2.06

   Registered Office; Registered Agent      13  
 

Section 2.07

   Powers      13  
 

Section 2.08

   Term      13  
 

Section 2.09

   Title to Property      13  
 

Section 2.10

   No Liability to Third Parties      14  
 

Section 2.11

   Other Business Opportunities; Independent Acquisition of Properties      14  
 

Section 2.12

   No Agency      14  
 

Section 2.13

   Priority of Agreements; Default Rules      15  
 

Section 2.14

   Liability Several      15  
 

Section 2.15

   Capacity of Members      15  
 

Section 2.16

   Tax Status      16  

ARTICLE III. MEMBERS

     16  
 

Section 3.01

   Members      16  
 

Section 3.02

   Units.      17  
 

Section 3.03

   Action by Members.      18  
 

Section 3.04

   Voting Rights      18  
 

Section 3.05

   Limitation of Liability of Members      18  
 

Section 3.06

   Unit Transfers      19  
 

Section 3.07

   No Right to Withdraw.      19  
 

Section 3.08

   Issuances of Additional Equity      19  
 

Section 3.09

   Exculpation and Indemnification      19  

ARTICLE IV. GOVERNANCE MATTERS

     21  
 

Section 4.01

   Management of Company      21  
 

Section 4.02

   Agreement to Take Corporate Actions      21  

ARTICLE V. MANAGEMENT OF OPERATIONS

     22  
 

Section 5.01

   Officers      22  
 

Section 5.02

   Information Rights      22  


              Page  

ARTICLE VI. DISTRIBUTIONS; REDEMPTION

     23  
 

Section 6.01

   Distributions on Preferred Units      23  
 

Section 6.02

   Distributions on Common Units      23  
 

Section 6.03

   Distributions Upon Liquidation      24  
 

Section 6.04

   Optional Redemption      25  

ARTICLE VII. TRANSFERS; PREFERENTIAL PURCHASE RIGHTS; EXEMPT TRANSFERS

     26  
 

Section 7.01

   Restrictions on Transfer.      26  
 

Section 7.02

   Permitted Transfers      26  
 

Section 7.03

   Transfer Procedures      27  
 

Section 7.04

   Exit Cooperation      28  

ARTICLE VIII. GOVERNING LAW; DISPUTES

     29  
 

Section 8.01

   Governing Law; Consent to Jurisdiction      29  
 

Section 8.02

   Dispute Resolution      29  
 

Section 8.03

   Continuing Obligations      29  
 

Section 8.04

   Waiver of Jury Trial      29  

ARTICLE IX. CONFIDENTIALITY; PUBLIC ANNOUNCEMENTS

     30  
 

Section 9.01

   General      30  
 

Section 9.02

   Exceptions      30  
 

Section 9.03

   Public Announcements      31  
 

Section 9.04

   Duration of Confidentiality      32  
 

Section 9.05

   Redacted Filings      32  

ARTICLE X. TERMINATION

     32  
 

Section 10.01

   Termination of Agreement      32  
 

Section 10.02

   Right to Data After Termination      33  

ARTICLE XI. GENERAL PROVISIONS

     33  
 

Section 11.01

   Notices      33  
 

Section 11.02

   Assignment      34  
 

Section 11.03

   Waiver      34  
 

Section 11.04

   Amendments      35  
 

Section 11.05

   Force Majeure      35  
 

Section 11.06

   Further Assurances      35  
 

Section 11.07

   Survival of Terms and Conditions      35  
 

Section 11.08

   Entire Agreement      35  

 

2


              Page  
 

Section 11.09

   Severability      36  
 

Section 11.10

   No Third-Party Beneficiary      36  
 

Section 11.11

   Time Is of the Essence      36  
 

Section 11.12

   Limitation of Liability      36  
 

Section 11.13

   Counterparts      36  

 

SCHEDULES      
Schedule A  —    Members   
Schedule B  —    Officers   
Schedule C  —    Form of Certificates   

 

3


LIMITED LIABILITY COMPANY AGREEMENT

This LIMITED LIABILITY COMPANY AGREEMENT (this “Agreement”) of Calcasieu Pass Funding, LLC, a Delaware limited liability company (the “Company”), is entered into as of August 19, 2019 by and among Venture Global Calcasieu Pass Holding, LLC, a Delaware limited liability company (“Sponsor”), and Stonepeak Bayou Holdings II LP, a Delaware limited partnership (“Investor”).

WHEREAS, the Company was formed by the filing of the Certificate of Formation with the Secretary of State of the State of Delaware pursuant to the Act (as defined below) on May 23, 2019;

WHEREAS, as of the date hereof, Sponsor has contributed $549,500,000 to the Company in exchange for Common Units (as defined below);

WHEREAS, on May 25, 2019, the Company, Sponsor and Investor entered into the Redeemable Preferred Unit Purchase Agreement relating to the issuance and sale of the Preferred Units (as defined below);

WHEREAS, the Company has elected to be treated as a corporation for U.S. federal income tax purposes;

AND WHEREAS Sponsor and Investor desire to establish certain rights and obligations between themselves as Members in accordance with the terms hereof.

NOW, THEREFORE, in consideration of the premises and the mutual agreements herein set forth, the receipt and sufficiency of which are hereby acknowledged, the Parties hereby agree as follows:

ARTICLE I.

DEFINITIONS

Section 1.01 Definitions.

As used in this Agreement, the following terms shall have the meanings given below.

Act” means the Delaware Limited Liability Company Act.

Affiliate” means (and as applicable as part of its derivative “Affiliated” means), with respect to any Person, the following: (i) any other Person that directly or indirectly, through one or more intermediaries, Controls such Person and (ii) any other Person that is Controlled by or under common Control with such Person.

Agreement” has the meaning set forth in the preamble.

Approved by Company”, “Approved by the Managing Member”, “Approval” or “Approved” means a proposal or action in respect of the Company that has been approved by the Managing Member in accordance with Article IV (subject to and without limiting, in each case, any applicable requisite consent of any Member(s), to the extent otherwise expressly required hereunder).


Available Cash” means (without duplication) all unrestricted and distributable cash and cash equivalents of the Company, without taking into account cash and cash equivalents of its subsidiaries and net of any taxes payable (including any tax distributions under any tax sharing agreement for so long as the Company is a member of a consolidated, combined, unitary or similar group of which it is not the common parent for U.S. federal, state or local Tax purposes and solely to the extent they are payments by the Company to the direct or indirect owner(s) of its Equity Interests for the purposes of payment of such taxes, in amounts not to exceed the product of (x) the taxable net income of the Company for the relevant period, taking into account any net taxable losses with respect to prior periods, and (y) the highest marginal effective rate for the relevant tax purposes imposed on a corporation doing business in the State of Louisiana (such tax distributions up to such amount, “Permitted Tax Distributions”)), including (to the extent unrestricted and distributable) the amount of Net LNG Sales Proceeds received by the Company, less any portion thereof set aside by the Managing Member in order to maintain reasonably adequate reserves for operations as reasonably determined by the Managing Member.

Base Return” means 100% of the Face Value, as increased (without duplication, but for the avoidance of doubt including any accrual and any cumulation) by any Accrued Distributions.

Business Day” means a day other than Saturday, Sunday or statutory holiday on which commercial banks located in the city of New York, New York are open for business during normal banking hours.

Calendar Year” means the period of 12 consecutive months starting on the first day of January at 12:00 a.m., Eastern standard time, and ending on the immediately following 31st day of December at 11:59 p.m. midnight, Eastern standard time. If any activity or event that is to be performed or that is to occur during or in respect of any Calendar Year established herein begins after January 1st of such Calendar Year, the period covered shall be the period from the time of commencement of the action or event through December 31st of the year in which the time of commencement occurs.

Capital Contribution” means, subject to any limitations imposed by Legal Requirements, any contribution to the capital of the Company by a Member in respect of its Units in cash, property, the use of property, services or otherwise, whenever made.

Certificate of Formation” means the certificate of formation of the Company as filed with the Secretary of State of the State of Delaware, as may be amended from time to time.

Change in Control Event” has the meaning set forth in Section 6.03(b).

Claims” has the meaning set forth in Section 3.09(b).

Closing Date” means the date on which the conditions precedent to the sale and purchase of the Preferred Units under the Redeemable Preferred Unit Purchase Agreement shall have been satisfied or waived, the Preferred Units shall have been issued hereunder and the purchase price therefor shall have been paid.

 

2


Code” means the United States Internal Revenue Code of 1986, as amended from time to time.

Commercial Operation Date” means the date on which: (a) each of the LNG Facility and the Lateral Pipeline have achieved “substantial completion” (or the equivalent) under the Facility EPC Agreements (as defined in the CP Holdings LLC Agreement) and the Pipeline EPC Agreement, respectively, including satisfactory completion of all commissioning and testing specified therein, and the LNG Facility has commenced operations in accordance with all performance guarantees; (b) all Project Costs (as defined in the CP Holdings LLC Agreement) due and payable have been paid, including any liquidated damages and final payments under Key Project Contracts (as defined in the CP Holdings LLC Agreement) (to the extent required by the Project Financing Documents), and all punch list and other remaining Project Costs, including any bonuses or other incentive payments owing to any counterparty, have been quantified and appropriate amounts have been set aside for the payment of such costs to the extent not paid; (c) each Foundation LNG SPA (as defined in the CP Holdings LLC Agreement) (together with each other Key Project Contract) and each Governmental Authorization then required for the operation of the Project shall be in full force and effect and no material default shall exist under any such Key Project Contract or Governmental Authorization; (d) the Company shall have notified each buyer under its relevant Foundation LNG SPA that the LNG Facility has become commercially operable and “commercial operation” (or the equivalent) shall have been achieved under each Foundation LNG SPA within the required time period after such notice (upon which designated commercial volumes of LNG are required to be delivered and taken under, and in accordance with, each such Foundation LNG SPA, notwithstanding any delivery of commissioning volumes prior thereto); and (e) the construction loans under the Project Financing have converted to term loans in accordance with the Project Financing Documents and no default or event of default exists under the Project Financing Documents.

Common Member” has the meaning set forth in Section 3.01.

Common Units” has the meaning set forth in Section 3.02(b).

Company” has the meaning set forth in the preamble.

Confidential Information” means the terms of this Agreement and any other information concerning any matters affecting or relating to the business, operations, assets, results or prospects of the Company or its subsidiaries, including information regarding plans, budgets, processes, except to the extent that such information has already been publicly released (in a manner that does not violate or breach this Agreement).

Control” means (and as applicable as part of its derivatives “Controls” and “Controlled” means) possession, directly or indirectly, of the power to vote 50% or more of the voting power of such Person or to otherwise direct or cause the direction of the management or policies of a Person, whether through ownership of the voting power of such Person, by contract or otherwise.

Covered Persons” has the meaning set forth in Section 3.09(a).

CP Holdings” means Calcasieu Pass Holdings, LLC.

 

3


CP Holdings LLC Agreement” means the LLC Operating Agreement of CP Holdings.

Default Rule” means a provision of the Act that would apply to the Company unless otherwise provided in, or modified by, this Agreement.

Distribution Rate” means:

 

  (a)

prior to the eighth anniversary of the Closing Date, a rate of 10.0% per annum;

 

  (b)

from and after the eighth anniversary of the Closing Date, a rate per annum equal to the sum of (i) 10.0% plus (ii) an additional 0.50% for every six-month period following such eighth anniversary, but shall in no event exceed 15.0% per annum.

Dollars”, “dollars” or “$” means currency of the United States of America unless otherwise specifically indicated.

Encumbrance” or “Encumbrances” means mortgages, charges, deeds of trust, security interests, pledges, liens, royalties, overriding royalty interests, preferential purchase rights or other encumbrances or burdens of any nature whether imposed by contract or operation of law.

Entity” means any corporation (including any non-profit corporation), company, limited liability company, limited duration company, general partnership, limited partnership, limited liability partnership, joint venture, joint stock association, estate, trust, cooperative foundation, union, syndicate, league, consortium, coalition, committee, society, firm or other enterprise, association, organization or entity of any nature recognized under the laws of any jurisdiction.

EPC Force Majeure” means a “Force Majeure” event under and as defined in any Facility EPC Agreement or the Pipeline EPC Agreement.

Equity Interests” of any Person means (a) any and all capital stock of such Person, or other equity interest or participation that confers on a Person the right to receive a share of the profits and losses of, or distributions of assets of, such Person, and (b) all rights to purchase, warrants or options (whether or not currently exercisable), participations or other equivalents of or interests in (however designated) such capital stock or other equity interest or participation.

Face Value” means, as of each time of determination, with respect to Preferred Units, the Initial Face Value, as may be increased pursuant to Section 6.01.

FERC” means the Federal Energy Regulatory Commission.

Force Majeure” means either an EPC Force Majeure or an LNG SPA Force Majeure.

Future Common Contributions” has the meaning set forth in Section 3.02(d).

GAAP” has the meaning set forth in Section 5.02(a)(i).

Governmental Authority” means any governmental authority, local authority or political subdivision of any of the foregoing, any multi-national organization or body, any agency,

 

4


department, commission, board, bureau, court or other authority thereof or any quasi-governmental or private body having jurisdiction or entitled to exercise any executive, legislative, judicial, administrative, police, regulatory or taxing authority or power of any nature.

Governmental Authorization” means any permit, license, franchise, approval, certificate, consent, ratification, permission, confirmation, endorsement, waiver, certification, registration, transfer, qualification or other authorization issued, granted, given or otherwise made available by or under the authority of any Governmental Authority or pursuant to any Legal Requirement.

Indebtedness” means any of the following: (a) the principal of and accrued interest, premium (if any) or penalties on, and premiums or penalties that would arise as a result of prepayment of, (i) any indebtedness for borrowed money of any kind, (ii) any obligations evidenced by bonds, debentures, notes or other similar instruments, (iii) any obligations, contingent or otherwise, under banker’s acceptance credit, letters of credit or similar facilities, (iv) any obligations representing capital lease obligations in respect of sale and leaseback transactions, (v) any obligations representing the net amount owing under any hedging obligations, and (vi) any obligation under conditional sale or other title retention agreements relating to purchased property or assets; (b) any obligations to pay the deferred purchase price of property, assets or services, except trade accounts payable and other current liabilities arising in the ordinary course of business; and (c) any guaranty of any of the foregoing.

Initial Capital Contribution” has the meaning set forth in Section 3.02(c).

Initial Face Value” means, with respect to Preferred Units, an initial value of $100.

Investment Fund” means any financial sponsor, investment fund, or any investment manager, administrator or advisor, or any similar firm or vehicle making financial investments in debt or equity securities or interests as part of the ordinary course of its business (in each case, including any alternative investment vehicles, parallel funds and parallel accounts, co-invest vehicles or other investment vehicles thereof), and any Affiliate thereof (excluding any such Affiliate that is a portfolio company, but for the avoidance of doubt including any such Affiliate that is a co-invest vehicle).

Investor” has the meaning set forth in the preamble.

Involved Parties” has the meaning set forth in Section 8.02(a).

IPO” means the initial sale of equity or equivalent securities of the Company, any of its subsidiaries or any successor to any of the foregoing (including pursuant to any restructuring, recapitalization or reorganization), to the public pursuant to an effective registration statement filed under the Securities Act (or any foreign reasonable equivalent).

Lateral Pipeline” has the meaning set forth in the definition of Lateral Pipeline Project.

Lateral Pipeline Project” means the development, design, financing, engineering, procurement, construction, installation, tying-in, testing, commissioning, completion, ownership, insurance, operation and maintenance of a 42-inch diameter, approximately 24-mile long natural

 

5


gas pipeline (the “Lateral Pipeline”) that is being developed by TCP and that will extend to the LNG Facility from interconnection points within the vicinity of Grand Cheniere Station in Cameron Parish, Louisiana.

Legal Requirement” means any law, statute, ordinance, decree, requirement, order, treaty, proclamation, convention, rule or regulation (or interpretation of any of the foregoing) of any Governmental Authority, any agreement with a Governmental Authority and the terms of any Governmental Authorization.

Liquidation Event” has the meaning set forth in Section 6.03(a).

LNG Facility” means the 10.0 MTPA (nameplate) natural gas liquefaction and LNG export facility being developed by the Project Company in Cameron Parish, Louisiana, including: (i) nine modular approximately 1.25 MTPA natural gas liquefaction blocks, (ii) two 200,000 cubic meter cryogenic LNG storage tanks, (iii) a marine terminal with two ship-loading berths for LNG vessels up to 185,000 cubic meters in capacity, (iv) a 620 MW onsite combined cycle gas turbine power plant, (v) a natural gas pretreatment system capable of treating approximately 2,024 MMSCFD of natural gas, (vi) a perimeter wall currently anticipated to be 31 feet high on the north, east, and south sides of the terminal site and a 26.5 feet high berm on the west side of the terminal site and associated surge protection walls, (vii) administration and operating and maintenance buildings, (viii) all required utilities, instruments, control systems and piping, and (ix) all associated real property interests (including any leased real property).

LNG Facility Project” means the development, design, financing, engineering, procurement, construction, installation, tying-in, testing, commissioning, completion, ownership, insurance, operation and maintenance of the LNG Facility.

LNG SPA Force Majeure” means a “Force Majeure” event under and as defined in any Foundation LNG SPA.

Lock-Up Period” means, (a) in respect of any Member other than Sponsor, the period commencing on the date hereof and ending on the first year anniversary of the Commercial Operation Date, and (b) in respect of Sponsor, the period commencing on the date hereof and ending on the first year anniversary of the Commercial Operation Date or, solely in respect of any direct Transfer, the Redemption in Full Date, if later than such first year anniversary.

Majority Approval” means the affirmative vote or written consent of the holders of a majority of the outstanding Preferred Units.

Managing Member” means the Sponsor.

Member Indemnitors” has the meaning set forth in Section 3.09(d).

Members” means Sponsor and Investor as owners of the Units, and “Member” means either one of them.

MMSCFD” means million standard cubic feet per day.

 

6


MTPA” means million tonnes of LNG per annum.

Net LNG Sales Proceeds” means (without duplication) the total amounts received by the Company from the sale by the Company and its subsidiaries of LNG produced and loaded at the LNG Facility prior to the Commercial Operation Date (such period, the “Pre-Commercial Production Period”), less: (1) the aggregate amount of costs incurred by the Company and its subsidiaries in respect of all natural gas purchased to operate the LNG Facility or a portion thereof and produce LNG during the Pre-Commercial Production Period; (2) the aggregate amount incurred by the Company and its subsidiaries during the Pre-Commercial Production Period in respect of all natural gas transportation capacity; (3) the aggregate amount of costs incurred by the Company and its subsidiaries during the Pre-Commercial Production Period to operate the LNG Facility, including operating expenses, labor, consumables, port services, line handling charges, insurance costs, debt service, and sales and use, property, ad valorem or similar taxes; (4) the Company’s and its subsidiaries’ estimated income taxes on the Net LNG Sales Proceeds; (5) amounts paid by the Company and its subsidiaries under each LNG sales agreement entered into with respect to LNG sold during the Pre-Commercial Production Period, such as demurrage or other charges; (6) any amounts required to pay any incentive payments to any contractor, including payments of a portion of revenues; (7) working capital costs; and (8) general and administrative overhead for intercompany services during the Pre-Commercial Production Period, and after giving effect to any allocation of such proceeds to pay for Project Costs pursuant to the Project Financing Documents.

Officer” has the meaning set forth in Section 5.01(a).

Party” means each of the Members and the Company individually, and “Parties” means the Members and the Company, collectively.

Percentage Interest” means, as of any date of determination, as to any Common Member with respect to Common Units the quotient obtained by dividing (a) the number of Common Units held by such Member by (b) the total number of outstanding Common Units. For avoidance of doubt, the Percentage Interest with respect to any Preferred Member shall at all times be zero.

Permitted Tax Distributions” has the definition set forth in the definition of Available Cash.

Permitted Upstream Transfer” means, (a) with respect to any Member that is or is Controlled by, or otherwise directly or indirectly owned in whole or in part by, an Investment Fund, any direct or indirect Transfer or issuance of equity ownership (i) in such Investment Fund that is generally passive (which, for purposes of this definition shall include equity ownership that does not (A) have the right to vote with respect to, or otherwise Control, the day-to-day management activities of such Investment Fund or (B) have more than customary limited rights or ability to participate in any decision-making with respect to any action or exercise any right of a Member under this Agreement, except for such rights as are generally provided under agreements generally applicable to (x) the investors in such Investment Fund or (y) investments by such Investment Fund), (ii) in the investment manager, administrator or advisor or other Person providing management, administrative or advisory services to such Investment Fund in the ordinary course of its and such Investment Fund’s business, or (iii) to such Investment Fund and

 

7


(b) with respect to any Member, (i) any offering of equity securities of such Member, or of any Person directly or indirectly having equity ownership of such Member, to the public pursuant to an effective registration statement filed under the Securities Act (or any foreign reasonable equivalent), (ii) any Transfer of equity securities of such Member, or of any Person directly or indirectly having equity ownership of such Member, that are listed on a national securities exchange and registered under the Securities Exchange Act of 1934 (or any foreign applicable law) and (iii) any Transfer of equity securities of Sponsor, provided, in each case of (a) and (b) above, that the transferee is not a Prohibited Person.

Person” means any individual (including a personal representative), trust, Entity or Governmental Authority.

Pipeline EPC Agreement” means the Pipeline Construction Agreement, dated as of January 23, 2019, by and between TPC and WHC, LLC, as amended by Amendment No. 1 to Pipeline Construction Agreement, dated as of June 28, 2019, and supplemented by LNTP No. 1 dated as of January 24, 2019 and LNTP No. 2 dated as of January 25, 2019, Change Order No. 1, dated as of June 13, 2019, Change Order No. 2, dated as of June 14, 2019, Change Order No. 3, dated as of July 19, 2019, and Full Notice to Proceed, dated as of June 28, 2019, by and between TCP and WHC, LLC.

Pledgor” means Calcasieu Pass Pledgor, LLC, a Delaware limited liability company and a direct wholly-owned subsidiary of the CP Holdings.

Preferred Member” has the meaning set forth in Section 3.01.

Preferred Preference Amount” has the meaning set forth in Section 6.03(a).

Preferred Units” has the meaning set forth in Section 3.02(b).

Prohibited Person” means any Person (other than Investor or Sponsor) that (i) is a foreign national oil or gas company, (ii) together with all of its Affiliates (taken as a whole) is primarily engaged in the business of developing, owning, or operating a greenfield national gas liquefaction project located in North America or an LNG export terminal located in North America; provided that this subpart (ii) shall not include Investment Funds investing in portfolio companies that qualify as Prohibited Persons pursuant to this subpart (ii); and provided, further, that such Person shall have entered into appropriate confidentiality arrangements and otherwise implemented and shall maintain internal institutional information barriers to prevent the disclosure to and use of the information of the Company and its Affiliates in respect of, for the benefit of or by such portfolio companies, (iii) is (or has any Affiliate, excluding portfolio companies, that is) engaged in any material litigation against the Company, its subsidiaries, the other Members or any of their respective Affiliates, (iv) any Investment Fund whose investment mandate is primarily to make financial investments in distressed equity or distressed debt securities (“Vulture Funds”), or any Affiliate of any such Vulture Fund that is reasonably identifiable based on the name of such Affiliate; provided, that this clause (iv) shall not include Affiliated Investment Funds, or portfolio companies or other Affiliates, of Vulture Funds, that do not have an investment mandate that is primarily to make financial investments in distressed equity or distressed debt securities so long as such Person shall have entered into appropriate confidentiality arrangements and otherwise

 

8


implemented and shall maintain internal institutional information barriers to prevent the disclosure to and use of the information of the Company and its Affiliates in respect of, for the benefit of or by such Vulture Fund, or (v) is (or has any Affiliate that is) subject to and will cause the Company or any of its subsidiaries to become subject to sanctions, counterterrorism, anti-money laundering or criminal actions or civil complaints predicated on fraud, corruption or material securities law violations, or any laws or proceedings similar to the foregoing.

Project” means the LNG Facility Project or the Lateral Pipeline Project, individually or collectively.

Project Company” means Venture Global Calcasieu Pass, LLC, a Delaware limited liability company and an indirect wholly-owned subsidiary of the Company.

Project Costs” means all costs of acquiring, leasing, designing, engineering, procuring, purchasing, developing (including costs incurred in connection with preparing for and implementing a Project Financing), optioning, permitting, insuring, constructing, installing, commissioning, testing and starting-up (including costs relating to all equipment, site preparation, materials, spare parts, gas, transportation, pre-commercial operation operating costs and labor for) the Project, together with financing costs, including interest during construction and reserves.

Project Financing” means all Project level debt financing for the construction, operation and maintenance of the Project to be obtained by the Project Company and/or TCP from one or more Senior Lenders.

Project Financing Documents” means the documents evidencing or setting forth the terms and conditions of the Project Financing.

Quarterly Distribution Date” means the distribution date established by the Managing Member as promptly as practicable following the last day of each calendar quarter (which shall, in any case, occur no later than thirty (30) days following the last day of such calendar quarter).

Redeemable Preferred Unit Purchase Agreement” means the Redeemable Preferred Unit, dated as of May 25, 2019, by and among Sponsor, the Company and the purchasers party thereto.

Redeemed in Full Date” means the date on which all of the outstanding Preferred Units have been redeemed in full.

Redemption Date” has the meaning set forth in Section 6.04(i).

Redemption Price” has the meaning set forth in Section 6.04(i).

Securities Act” means the Securities Act of 1933, as amended.

Senior Lenders” means the commercial banks and other institutional lenders (including any such lenders purchasing debt securities of the Project Company and/or TCP) that are party to the Project Financing, together with any agent or trustee therefor.

 

9


Specified Covered Persons” has the meaning set forth in Section 3.09(d).

Sponsor” has the meaning set forth in the preamble.

TCP” means TransCameron Pipeline, LLC, a Delaware limited liability company and an indirect wholly-owned subsidiary of the Company.

Transfer” (a) when used as a verb, means, directly or indirectly, to sell, grant, assign, create an Encumbrance on, pledge, charge or otherwise convey, or dispose of or commit to do any of the foregoing (and “Transferred” shall have the correlative meaning) and (b) when used as a noun, means a direct or indirect sale, grant, assignment, Encumbrance, pledge, charge, conveyance or other disposition (and “Transferor” and “Transferee” shall have the correlative meaning). For avoidance of doubt, any sale, assignment, or other transfer of any part or all of Investor by any parent entity of Investor shall constitute a Transfer.

Units” means the units into which the interests in the Company are divided.

Vulture Funds” has the meaning set forth in the definition of Prohibited Person.

Section 1.02 Interpretation, Etc.

This Agreement is the result of negotiations among the Parties, and the terms and provisions hereof (except where otherwise defined or the context otherwise requires) shall be construed in accordance with their usual and customary meanings. The captions or headings of sections or subsections of this Agreement are for purposes of reference only and shall not limit or define the meaning of any provision of this Agreement. Insofar as is permissible under applicable Legal Requirements, the Parties hereby waive the application of any rule of law that ambiguous or conflicting terms or provisions should be construed against the Party who (or whose attorney) prepared the executed agreement or any earlier draft of the same. Any of the terms defined herein may, unless the context otherwise requires, be used in the singular or the plural, depending on the reference. References herein to any Section or Schedule shall be to a Section or Schedule, as the case may be, hereof unless otherwise specifically provided. The use herein of the word “include” or “including”, when following any general statement, term or matter, shall not be construed to limit such statement, term or matter to the specific items or matters set forth immediately following such word or to similar items or matters, whether or not non limiting language (such as “without limitation” or “but not limited to” or words of similar import) is used with reference thereto, but rather shall be deemed to refer to all other items or matters that fall within the broadest possible scope of such general statement, term or matter. The phrases “directly or indirectly” or “direct or indirect”, when used in the context of ownership, holdings, Control, Transfer, investment or acquisition include ownership, holdings, Control, Transfer, investment or acquisition, as applicable, through a chain of direct or indirect beneficial ownership or Control of one or more Persons. Where any provision in this Agreement refers to Transfers by any Person, such provision will be applicable whether such Transfer is made directly by such Person or by any Person directly or indirectly owning or holding any Equity Interests in such Person (it being understood and agreed, for the avoidance of doubt, that the provisions of this Agreement relating to any Transfer by any Member or any Transfer of the Equity Interests then owned by any Member shall be deemed to also apply to any Transfer of any Equity Interests in any Person directly or indirectly holding

 

10


any Equity Interests in such Member). As used herein, the terms “portfolio company” and “co-invest vehicle” shall have the meanings commonly ascribed to such terms in the private equity industry. The terms “lease” and “license” shall include “sub-lease” and “sub-license”, as applicable. In this Agreement in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each mean “to but excluding”. Unless the context otherwise expressly requires, the word “or” shall not be exclusive. References in this Agreement to any Person shall mean and be a reference to such Person and its successors and permitted assigns (including in the case of any Member, such Member’s direct Transferees in respect of any Units directly Transferred in accordance with this Agreement). References in this Agreement to any agreement or contract, unless otherwise specified, shall mean and be a reference to such agreement or contract as amended, amended and restated, supplemented or otherwise modified from time to time in accordance with its terms. References in this Agreement to any Person shall mean and be a reference to such Person and its successors and permitted assigns (including in the case of any Member, such Member’s direct Transferees to the extent permitted under this Agreement). Where the term “subject to applicable Legal Requirements” is used, any applicable Legal Requirement shall govern or limit the referenced matter or action except to the extent that such Legal Requirement can be waived or overridden by agreement, in which case such Legal Requirement shall be deemed to have been waived and overridden by this Agreement to the extent that terms hereof conflict with such Legal Requirement within the limits of such permitted waiver or override. If and to the extent there is such a conflict which cannot be avoided, the Parties will work together in good faith using all available legal means (within reason) to carry into effect the intent of the Parties as evidenced by this Agreement.

Section 1.03 Schedules.

The following Schedules are attached to and form part of this Agreement:

 

Schedule A

     

Members

Schedule B

     

Officers

Schedule C

     

Form of Certificates

ARTICLE II.

ORGANIZATIONAL MATTERS

Section 2.01 Formation.

The Company was formed on May 23, 2019 pursuant to the Act by the filing of the Certificate of Formation with the Secretary of State of the State of Delaware.

Section 2.02 Name.

The name of the Company is “Calcasieu Pass Funding, LLC”. All business of the Company will be conducted in such name or such other name as is Approved by the Managing Member.

 

11


Section 2.03 Purpose.

The purpose of the Company shall be to engage in any lawful business, purpose or activity that may be engaged in by a limited liability company organized under the Act, provided, however, that the Company shall not, except with prior written Majority Approval:

(a) engage in any business other than owning Equity Interests in CP Holdings and activities reasonably related thereto (including exercising its rights and performing its obligations pursuant to CP Holdings LLC Agreement and consummating dispositions of the Equity Interest in CP Holdings to the extent permitted under CP Holdings LLC Agreement and this Agreement) and will not own any other assets or incur any other liabilities;

(b) form or have any direct or indirect subsidiary other than CP Holdings and (indirectly through CP Holdings) its direct and indirect subsidiaries, or own any Equity Interest in any other Person other than the Equity Interests in CP Holdings;

(c) issue any Equity Interests in the Company that rank senior to or pari passu with the Preferred Units;

(d) incur any Indebtedness, or create, incur, assume or otherwise cause or permit to exist any Encumbrance of any kind on the Equity Interests held or owned by, or other assets of, the Company, unless the proceeds of such Indebtedness redeems all of the issued and outstanding Preferred Units in full in accordance with Section 6.04 concurrently with the incurrence of such Indebtedness;

(e) Transfer any Equity Interests of CP Holdings held by the Company (other than indirect Transfers effected solely through Transfers of Equity Interests of the Company);

(f) make any payment to, or enter into any transaction, contract or agreement with any Common Member or any of its Affiliates, other than (i) the tax sharing agreement referenced in the definition of “Available Cash”, (ii) Permitted Tax Distributions and other distributions in respect of the Common Units expressly permitted by the other sections of this Agreement and (iii) reasonable reimbursements for general and administrative out-of-pocket expenses (with reasonable supporting documentation to the extent requested by Majority Approval) incurred on behalf of the Company for its operation and maintenance in accordance with this Agreement, whether pursuant to any formal agreement or arrangement or otherwise;

(g) make any purchase or redemption of any Common Units; or

(h) use any cash or cash equivalents for any purpose other than to pay distributions or expenses of the Company in accordance with this Agreement or hold any such cash or cash equivalents other than in deposit accounts or securities accounts of the Company invested only in (i) cash, (ii) marketable obligations, maturing within twelve (12) months after acquisition thereof, issued or unconditionally guaranteed by the United States or an instrumentality or agency thereof and entitled to the full faith and credit of the United States and (iii) marketable direct obligations issued or fully guaranteed by any state of the United States or any political subdivision of any such state or any public instrumentality thereof maturing within one (1) year from the date of acquisition thereof and, at the time of acquisition, having one of the two highest ratings obtainable from either S&P or Moody’s.

 

12


Section 2.04 Principal Place of Business; Foreign Qualifications.

The principal place of business of the Company shall be located at such location as may hereafter be determined by the Managing Member. The location of the Company’s principal place of business may be changed by the Managing Member from time to time in accordance with the then applicable provisions of the Act and any other applicable Legal Requirements. The Managing Member may file or cause to be filed for recordation in the proper office or offices in each other jurisdiction in which the Company is formed or qualified, such certificates to establish, continue or terminate the qualification of the Company as a foreign limited liability company in all such jurisdictions in which the Company may conduct business.

Section 2.05 Fiscal Year.

The fiscal year for the Company shall be the Calendar Year.

Section 2.06 Registered Office; Registered Agent.

The address of the registered office of the Company as of the date of this Agreement is Corporation Trust Center, 1209 Orange Street, Wilmington, Delaware 19801. The registered agent of the Company on the date of this Agreement is The Corporation Trust Company. The Managing Member may designate another registered agent or registered office from time to time in accordance with the then applicable provisions of the Act and any other applicable Legal Requirements.

Section 2.07 Powers.

The Company shall have the power and authority to take any and all actions that are necessary, appropriate, advisable, convenient or incidental to, or for the furtherance of, the purposes set forth in Section 2.03.

Section 2.08 Term.

The term of the Company commenced on the date of the initial filing of the Certificate of Formation with the Secretary of State of the State of Delaware and shall continue in perpetuity, unless sooner terminated in accordance with Article X or the Act.

Section 2.09 Title to Property.

All real and personal property owned or leased by the Company shall be owned or leased by the Company as an entity and no Member shall have any ownership or leasehold interest in such property in its individual name, and each Member’s interest in the Company shall be personal property for all purposes. Except as otherwise provided in this Agreement, the Company shall hold all of its real and personal property in the name of the Company and not in the name of any Member.

 

13


Section 2.10 No Liability to Third Parties.

The debts, obligations and liabilities of the Company, whether arising in contract, tort or otherwise, shall be solely the debts, obligations and liabilities of the Company, and no Member or officer shall be obligated personally for any such debt, obligation or liability of the Company solely by reason of being a Member or acting as an officer.

Section 2.11 Other Business Opportunities; Independent Acquisition of Properties.

Notwithstanding anything to the contrary in this Agreement or the Act, the doctrine of corporate opportunity, or any analogous doctrine, shall not apply to either Member or to any Managing Member. Except as expressly provided in this Agreement, each Member shall have the right independently to engage in and receive full benefits from business activities, whether or not competitive with operations conducted hereunder, without consulting the other Member. Sponsor shall not have any duty to the Company or any Member by reason of this Agreement to present any particular corporate, business or investment opportunity (including any opportunity with respect to the sale and purchase of LNG) to the Company or any Member, even if such opportunity is of a character that, if presented to the Company, could be taken by the Company or any of its subsidiaries, and any purported failure will not be deemed to be a breach of this Agreement, the Act or any other applicable law, and Sponsor shall continue to have the right to take for its own accounts or as a partner, shareholder, fiduciary or otherwise, or to recommend to others, any such particular opportunity. Investor shall not have any duty to the Company or any Member by reason of this Agreement to present any particular corporate, business or investment opportunity to the Company or any Member, even if such opportunity is of a character that, if presented to the Company, could be taken by the Company or any of its subsidiaries, and any purported failure will not be deemed to be a breach of this Agreement, the Act or any other applicable law, and each Investor shall continue to have the right to take for its own accounts or as a partner, shareholder, fiduciary or otherwise, or to recommend to others, any such particular opportunity. To the fullest extent permitted by applicable law, each Member (in its own name and in the name and on behalf of the Company) expressly waives any conflicts of interest or potential conflicts of interest and agrees that no Member or its Affiliates shall have any liability to any Member, any Affiliate thereof, or the Company with respect to such business or investment opportunities or any such related direct competition, conflicts of interest or potential conflicts of interest, and none of the same shall constitute a breach of this Agreement or of any duty expressed or implied by law to any Member or the Company. Each Member (in its own name and in the name and on behalf of the Company) acknowledges, affirms and agrees that (i) the execution and delivery of this Agreement by the Members is of material benefit to the Company and the Members, and that no Member would be willing to (x) execute and deliver this Agreement, and (y) hold the Units, without the benefit of this Section 2.11 and the agreement of the parties; and (ii) they have reviewed and understand the provisions of Sections 18-1101(b) and (c)  of the Act.

Section 2.12 No Agency.

Nothing contained in this Agreement or in the Certificate of Formation shall be deemed to constitute any Member the partner of any other Member, respectively, to create any fiduciary relationship between them, nor, except as otherwise herein expressly provided, to constitute any Member the agent or legal representative of any other Member, respectively. No Member shall

 

14


have any authority to act for or to assume any obligation or responsibility on behalf of the other Member in its individual capacity, except as otherwise expressly provided herein. Each Member shall indemnify, defend and hold harmless the other Member and its Affiliates, their directors, managers, officers, employees, agents and attorneys, from and against any and all losses, claims, damages and liabilities arising out of any act or assumption of liability by the indemnifying Member or any of their respective directors, managers, officers, employees, agents or attorneys, done or undertaken, or apparently done or undertaken, on behalf of the other Member or the Company, except pursuant to authority expressly granted in the Certificate of Formation or in this Agreement or conferred in writing by the Managing Member. Nothing in this Section 2.12 shall be deemed to lessen any power or authority, express or implied, of any director, manager, officer or committee of the Company.

Section 2.13 Priority of Agreements; Default Rules.

(a) This Agreement is the “limited liability company agreement” of the Company within the meaning of Section 18-101(7) of the Act. To the extent permitted by applicable Legal Requirements and the Act and as among the Members, the provisions of this Agreement shall apply to any matter related to the Company that is not covered by the Certificate of Formation. In the event of any inconsistency between the terms and conditions of the Certificate of Formation and the terms and conditions of this Agreement, the terms and conditions of this Agreement, to the extent permitted by the Act, shall apply by the means set out in the following sentence. The Members shall, subject to the Act, take such action as may be appropriate, including amending the Certificate of Formation, to remove such conflict, ambiguity or inconsistency and to permit the Company and its affairs to be carried on in accordance with this Agreement.

(b) Regardless of whether this Agreement specifically refers to a particular Default Rule, to the extent permitted under the Act, (i) if any provision of this Agreement conflicts with a Default Rule, the provision of this Agreement shall control and such Default Rule is hereby modified or negated accordingly and (ii) if it is necessary to construe a Default Rule as modified or negated in order to effectuate any provision of this Agreement, such Default Rule is hereby modified or negated accordingly.

Section 2.14 Liability Several.

The rights, duties, obligations and liabilities of the Members under the Certificate of Formation and this Agreement shall be several and not joint or collective. Each Member shall be responsible only for its obligations as set out in the Certificate of Formation and in this Agreement and shall be liable only for its share of costs and expenses as provided herein.

Section 2.15 Capacity of Members.

(a) General. As of the date hereof, Sponsor represents and warrants to Investor and Investor represents and warrants to Sponsor that, with respect to itself:

(i) it is duly organized and in good standing in its place of organization;

 

15


(ii) it has the capacity to enter into and perform this Agreement and all transactions contemplated herein and all corporate and other actions required to authorize it to enter into and perform this Agreement have been properly taken;

(iii) it is not subject to any governmental order, judgment, decree, debarment, sanction or laws that would preclude the execution or implementation of this Agreement;

(iv) this Agreement has been duly executed and delivered by it and is valid and binding upon it in accordance with its terms;

(v) it owns its Units free of any Encumbrances (other than those set forth in this Agreement);

(vi) no Person has any right or option to acquire from it or its Affiliates, directly or indirectly, any right, title or interest of any nature in or to its Units; and

(vii) it is a “United States person” within the meaning of Section 7701(a)(30) of the Code.

(b) Survival. The representations and warranties contained in Section 2.15(a) shall survive the execution hereof for a period of two years from the date hereof. The time permitted for bringing a claim may be affected by any applicable limitation periods under applicable Legal Requirement of the State of Delaware.

Section 2.16 Tax Status.

It is the intent of the Members that the Company be taxed as a corporation for U.S. federal, state, and local tax purposes. The Managing Member shall at the Company’s expense prepare and file or cause to be prepared, filed and distributed all tax forms and returns required of the Company.

ARTICLE III.

MEMBERS

Section 3.01 Members.

The Members of the Company as of the date of this Agreement and their addresses shall be listed on Schedule A and said schedule shall be amended from time to time to reflect the withdrawal of Members and the admission of additional Members pursuant to this Agreement without requiring an amendment to this Agreement. The Members shall constitute a single class or group of members of the Company for all purposes of the Act, unless otherwise explicitly provided herein. The Managing Member shall promptly notify the Members of any changes in Schedule A, which (to the extent in accordance with this Agreement) shall constitute the record list of the Members for all purposes of this Agreement and the Managing Member shall provide a copy of Schedule A to any Member upon request. Members may designate a different address by a notice given to the Company and, upon delivery of such notice, the Managing Member shall so amend Schedule A hereto to reflect such change and provide a copy of such amended Schedule A to each Member. Members holding (a) Preferred Units are individually referred to herein as a “Preferred Member” and collectively as the “Preferred Members” and (b) Members holding

 

16


Common Units are individually referred to herein as a “Common Member” and collectively as the “Common Members”; provided that to the extent that Members hold more than one class of Units, the term “Preferred Member” shall only refer to any Member holding Preferred Units with respect to its Preferred Units only and the term “Common Member” shall only refer to any Member holding Common Units with respect to its Common Units only.

Section 3.02 Units.

(a) General. The Members shall have no interest in the Company other than the interest conferred by this Agreement representing, with respect to any Member at any particular time, that Member’s membership interests (including its rights as a Member hereunder), which shall be represented by such Member’s Units. Every Member by virtue of having become a Member shall be held to have expressly assented and agreed to the terms hereof and to have become a party hereto. Ownership of a Unit shall not entitle a Member to any title in or to the whole or any part of the property of the Company or right to call for a partition or division of the same by court decree or operation of law or for an accounting, or for the right to own or use particular or individual assets of the Company or any of its subsidiaries. Except as expressly provided herein, each Member agrees and acknowledges that the business and affairs of the Company shall be managed exclusively by the Managing Member.

(b) Initial Designation.

(i) The Company is initially authorized to have two (2) classes of Units, designated as Common Units (“Common Units”) and Perpetual Preferred Units (“Preferred Units”). Except as expressly provided herein, including subject to Section 2.03, clause (ii) below and Section 3.08, the Managing Member has the exclusive authority to issue Units and to authorize additional Units for issuance. The Units issued to a Member may be represented by a certificate, at the request of such Member.

(ii) Notwithstanding anything in clause (i) above to the contrary, the Preferred Units, with respect to distribution rights and distributions upon liquidation, winding-up and dissolution of the Company, rank senior to all other Units.

(iii) The Common Units, with respect to distribution rights and distributions upon liquidation, winding-up and dissolution of the Company, rank junior to all Preferred Units.

(c) Initial Capital Contribution. Each Member has made or is deemed to have made an initial Capital Contribution, if any, allocated among Units on Schedule A (each, an “Initial Capital Contribution”). Schedule A shall also set forth the agreed upon initial capital account of each of Sponsor and Investor. No Member shall be required to make any additional Capital Contributions to the Company without the consent of such Member. Any non-cash contributions will be valued at their fair market value, as determined in good faith by the Managing Member.

(d) Subsequent Capital Contributions. No Member shall have the obligation to make additional Capital Contributions, provided, however, that the Common Member shall have the right in its sole discretion to make additional Capital Contributions in exchange for additional Common Units without Majority Approval (“Future Common Contributions”).

 

17


(e) Certificates. The Company hereby irrevocably elects that all of the Units shall constitute securities within the meaning of Article 8 of the Uniform Commercial Code (including Section 8-102(a)(15) thereof) as in effect from time to time in the State of Delaware and each other applicable jurisdiction. Each certificate evidencing the Units shall bear the following legend: “THIS CERTIFICATE EVIDENCES A MEMBERSHIP INTEREST IN CALCASIEU PASS FUNDING, LLC AND SHALL BE A SECURITY GOVERNED BY ARTICLE 8 OF THE UNIFORM COMMERCIAL CODE AS IN EFFECT IN THE STATE OF DELAWARE AND, TO THE EXTENT PERMITTED BY APPLICABLE LAW, EACH OTHER APPLICABLE JURISDICTION.” All Units shall be represented by a certificate in the form of Schedule E attached hereto and, accordingly, each such certificate shall be deemed to be a “certificated security” within the meaning of the UCC. This Section 3.02(e) may not be amended or modified so long as any of the Preferred Units or Common Units are subject to a pledge or hypothecation without the prior written consent of such pledgee (or the transferee of such pledgee).

(f) No Reduction in Member’s Units. Except as otherwise provided in this Agreement or any award hereunder, the number of Units held by a Member shall not be reduced without such Member’s consent.

Section 3.03 Action by Members.

No annual meeting of Members is required to be held. Any action required or permitted to be taken at any meeting of Members may be taken without a meeting if one or more written consents to such action shall be signed by the Members holding the amount of Units required to approve the action being taken. Such written consents shall be delivered to the Managing Member at the principal office of the Company and to any Member that did not sign such written consent and, unless otherwise specified in any unanimous written Member consent, shall be effective on the date when the consent is so delivered and notice thereof is provided. The Managing Member shall give prompt notice to all Members who did not consent to any action taken by written consent of Members without a meeting. No Person holding a Unit shall have any right to vote, approve, consent or participate in any decision by the Company or the Managing Member in any way except as specifically set forth herein or as required by applicable law.

Section 3.04 Voting Rights.

Except as otherwise specifically provided herein or required by law, each outstanding Common Unit shall entitle the holder thereof to one vote on all matters for which the holders of Common Units are entitled to vote after the Redemption in Full Date. Unless otherwise required by the Act or specified elsewhere in this Agreement, all approvals and consents to be taken or given by the Members after the Redemption in Full Date shall require the affirmative vote or the written consent in accordance with Section 3.03 of the holders of a majority of the Percentage Interest entitled to vote thereon.

Section 3.05 Limitation of Liability of Members.

Except as otherwise provided in the Act, no Member of the Company shall be obligated personally for any debt, obligation or liability of the Company or of any other Member, whether arising in contract, tort or otherwise, solely by reason of being a Member of the Company. Except

 

18


as otherwise provided in the Act, by law or expressly in this Agreement, no Member shall have any fiduciary or other duty to another Member with respect to the business and affairs of the Company, and no Member shall be liable to the Company or any other Member for acting in good faith reliance upon the provisions of this Agreement. No Member shall have any responsibility to restore any negative balance in its capital account or to contribute to or in respect of the liabilities or obligations of the Company or return distributions made by the Company except as required by the Act or other applicable law. The failure of the Company to observe any formalities relating to the exercise of its powers or the management of its business or affairs under this Agreement or the Act shall not be grounds for making its Members or Officers responsible for any liability of the Company.

Section 3.06 Unit Transfers.

No Member shall, during the term of this Agreement, Transfer any of the Units now owned or hereafter acquired by it, except in compliance with the provisions this Agreement. The Company will not cause or permit the Transfer of its Units to be made on its register or other books unless the Transfer is permitted or required by the provisions hereof, and will not issue any Units or other equity interests whether by original issue, in connection with the sale of any outstanding equity interests of Company or in connection with any Transfer, except in accordance with the terms hereof. All Transfers of a Member’s Units shall be subject to the limitations on transferability set forth in Article VII. A notice reflecting the substance of such restrictions shall be entered in Schedule A.

Section 3.07 No Right to Withdraw.

Except as set forth in Article VII with respect to Transfers of Units, no Member shall have any right to resign or withdraw from the Company without the written consent of the other Members. Any Member resigning or withdrawing in contravention of this Section 3.07 shall indemnify, defend and hold harmless the Company and all other Members from and against any losses, expenses, judgments, fines, settlements or damages suffered or incurred by the Company or any such other Member arising out of or resulting from such resignation or withdrawal. No Member shall have any right to receive any distribution or the repayment of its Capital Contribution, except as provided in Article VI. For the avoidance of doubt, any Member wrongfully resigning or withdrawing from the Company shall automatically forfeit all rights to future distributions from the Company, other than with respect to any distributions which have been declared, but unpaid as of any such resignation or withdrawal.

Section 3.08 Issuances of Additional Equity.

Except for Future Common Contributions or upon Majority Approval, the Company shall not issue, offer or sell, or cause to be issued, offered or sold, additional Units or to exchange or cause to be exchanged additional Units for securities or other property.

Section 3.09 Exculpation and Indemnification.

(a) Exculpation. Notwithstanding any other provisions of this Agreement, whether express or implied, or obligation or duty at law or in equity, none of (i) the Members or any officers, directors, unitholders, partners, members, employees, representatives or agents of any of

 

19


the foregoing, or (ii) the Managing Member or officers of Company (the Persons identified in clauses (i), and (ii), collectively, the “Covered Persons”) nor any former Covered Person shall be liable to Company or any other Person for any act or omission (in relation to Company, this Agreement, any related document or any transaction or investment contemplated hereby or thereby) taken or omitted in good faith by a Covered Person and in the reasonable belief that such act or omission is in or is not contrary to the best interests of Company and is within the scope of authority granted to such Covered Person by this Agreement; provided that a court of competent jurisdiction shall not have determined that such act or omission constitutes fraud, willful misconduct or bad faith.

(b) Indemnification. To the fullest extent permitted by law, Company shall indemnify and hold harmless each Covered Person and each former Covered Person from and against any and all losses, claims, demands, liabilities, expenses, judgments, fines, settlements and other amounts arising from any and all claims, demands, actions, suits or proceedings, civil, criminal, administrative or investigative (“Claims”), in which Covered Person may be involved, or threatened to be involved, as a party or otherwise, by reason of its management of the affairs of Company or which relates to or arises out of Company or its property, business or affairs. A Covered Person or former Covered Person shall not be entitled to indemnification under this Section 3.09 with respect to (i) any Claim with respect to which a court of competent jurisdiction has determined that such Covered Person has engaged in fraud, willful misconduct or bad faith, or (ii) any Claim initiated by such Covered Person unless such Claim (or part thereof) (A) was brought to enforce such Covered Person’s rights to indemnification hereunder or (B) was authorized or consented to by the Managing Member. Expenses incurred by a Covered Person in defending any Claim shall be paid by Company in advance of the final disposition of such Claim upon receipt by Company of an undertaking by or on behalf of such Covered Person to repay such amount if it shall be ultimately determined that such Covered Person is not entitled to be indemnified by Company as authorized by this Section 3.09.

(c) Effect of Modification. Any repeal or modification of this Section 3.09 shall not adversely affect any rights of such Covered Person pursuant to this Section 3.09, including the right to indemnification and to the advancement of expenses of a Covered Person existing at the time of such repeal or modification with respect to any acts or omissions occurring prior to such repeal or modification.

(d) Indemnitor of First Resort. Company hereby acknowledges that certain Covered Persons (the “Specified Covered Persons”) may have rights to indemnification and advancement of expenses provided by a Member or its Affiliates (directly or by insurance retained by such entity) (collectively, the “Member Indemnitors”). Company hereby agrees and acknowledges that (i) it is the indemnitor of first resort with respect to the Specified Covered Persons, (ii) it shall be required to advance the full amount of expenses incurred by the Specified Covered Persons, as required by the terms of this Agreement (or any other agreement between Company and the Specified Covered Persons), without regard to any rights the Specified Covered Persons may have against the Member Indemnitors and (iii) it irrevocably waives, relinquishes and releases the Member Indemnitors from any and all claims against the Member Indemnitors for contribution, subrogation or any other recovery of any kind in respect thereof. Company further agrees that no advancement or payment by the Member Indemnitors on behalf of Company with respect to any Claim for which the Specified Covered Persons have sought indemnification from Company shall

 

20


affect the foregoing, and the Member Indemnitors shall have a right of contribution and be subrogated to the extent of such advancement or payment to all of the rights of recovery of the Specified Covered Persons against Company.

(e) Non-Exclusivity of Rights. The rights conferred on any Covered Person by this Section 3.09 shall not be exclusive of any other rights that such Covered Person may have or hereafter acquire under any statute, provision of this Agreement, agreement, vote of Members or otherwise.

ARTICLE IV.

GOVERNANCE MATTERS

Section 4.01 Management of Company.

(a) Management by Managing Member. Subject to the terms of this Agreement and the express rights of the Preferred Members, the management and control of Company and its business and affairs, and the power to act for and to bind Company, shall be vested exclusively in the Managing Member. The Managing Member shall act as a “manager” pursuant to Section 18-402 of the Act.

Section 4.02 Agreement to Take Corporate Actions.

(a) Subject to applicable Legal Requirements, the Members shall themselves do and pass, and/or cause Company at all times thereafter to do and pass, or cause to be done and passed in a timely manner without undue delay, all such acts, meetings, resolutions and corporate actions, and from time to time execute and deliver or cause to be executed and delivered such documents, instruments and agreements as may be required under applicable Legal Requirements or as may be necessary or advisable in the reasonable opinion of any Member, to give effect to and to be responsive to and consistent with the terms and provisions of this Agreement, and to resolutions Approved by Company so that the Members and Company will become subject to all of the obligations and liabilities expressed to be imposed upon them respectively hereunder and the intentions of the Members expressed hereunder can be implemented. The Members agree to attend duly called meetings and vote their Units and otherwise to act in every manner permitted under applicable Legal Requirements, to cause Company to act in the manner provided for herein and in the manner set forth in duly Approved resolutions of the Managing Member and to give effect to the provisions of this Agreement and its purpose and intent, and to the extent necessary and permitted by Legal Requirements.

(b) Following the Commercial Operation Date, subject to applicable Legal Requirements and limitations contained in the Project Financing Documents, the Company shall cause the Company’s subsidiaries (including CP Holdings, Project Company and Pledgor) to distribute all of its Available Cash to the Company on a quarterly basis.

 

21


ARTICLE V.

MANAGEMENT OF OPERATIONS

Section 5.01 Officers.

(a) Designation of Officers. The business of the Company shall be managed under the direction of the Managing Member (and the Managing Member shall be deemed to be the manager of the Company as set forth in Section 4.01 hereof) who may exercise all the powers of the Company, except as provided by law or this Agreement. The Managing Member shall have the discretion to determine the duties of one or more of the following officers of the Company and any other officers it deems appropriate: a Chief Executive Officer, a President, a Chief Operating Officer, a Chief Financial Officer, one or more Vice-Presidents, a Secretary, a Treasurer, one or more Assistant Secretaries, one or more Assistant Treasurers and any other officers that the Managing Member deems necessary or convenient for the operation of the Company (each individually an “Officer” and, collectively the “Officers”) and shall have the authority to delegate any or all of its duties as manager to certain of such Officers. The Officers, to the extent of their powers, authority and duties set forth in this Agreement or otherwise vested in them by the Managing Member, are agents of the Company for the purposes of the Company’s business and the actions of the Officers taken in accordance with such powers shall bind the Company. As of the date of this Agreement, the Officers of the Company are set forth on Schedule D.

(b) Qualification; Removal. The Officers may be Members and shall hold office until their death, resignation or removal by the Managing Member. Any Officer may resign as such at any time. Such resignation shall be made in writing and shall take effect at the time specified therein, or if no time is specified, at the time of its receipt by the Managing Member. The acceptance of a resignation shall not be necessary to make it effective, unless expressly so provided in the resignation. All employees, agents and Officers shall be subject to the supervision and direction of the Managing Member and may be removed, with or without cause, from such office by the Managing Member and the authority, duties or responsibilities of any employee, agent or Officer of the Company may be suspended by or altered by the Managing Member from time to time.

Section 5.02 Information Rights.

(a) General Information Rights. The Company will furnish to each Member the following information:

(i) As soon as available, but no later than one-hundred twenty (120) days following completion of each fiscal year, the audited consolidated balance sheet of the Company and its subsidiaries as at the end of each such fiscal year and the audited consolidated statements of income, cash flows and changes in stockholders’ equity for such year of the Company and the subsidiaries, setting forth, in each case, in comparative form the figures for the next preceding fiscal year, accompanied by the report of independent certified public accountants of recognized national standing, to the effect that, except as set forth therein, such consolidated financial statements have been prepared in accordance with United States generally accepted accounting principles (“GAAP”) applied on a basis consistent with prior years and fairly present in all material respects the financial condition

 

22


of the Company and the subsidiaries as of the dates thereof and the results of their operations and changes in their cash flows and stockholders’ equity for the periods covered thereby.

(ii) As soon as available, but no later than sixty (60) days following completion of each fiscal quarter (other than the fourth fiscal quarter), the consolidated balance sheet of the Company and the subsidiaries as at the end of such quarter and the consolidated statements of income, cash flows and changes in stockholders’ equity for such quarter and the portion of the fiscal year then ended of the Company and the subsidiaries, setting forth, in each case, the figures for the corresponding periods of the previous fiscal year in comparative form, all in reasonable detail and all prepared in accordance with GAAP consistently applied (subject to normal year-end adjustments and the absence of footnotes).

(b) Tax Information Rights. Within 120 days after the end of each fiscal year, the Company shall cause to be delivered to each Member (so long as such Member owned any Units during such prior fiscal year) all information necessary for the preparation of such Member’s income tax returns (whether federal, state or foreign).

(c) Investor Information Rights. From and after the Closing Date, the Company shall provide the Members with customary reports and information with respect to the Company as may be reasonably requested by any Member.

ARTICLE VI.

DISTRIBUTIONS; REDEMPTION

Section 6.01 Distributions on Preferred Units.

(a) Each outstanding Preferred Unit shall be entitled to receive distributions either (i) if so declared by the Managing Member, from Available Cash at the Distribution Rate, or (ii) if the Managing Member does not declare a distribution from Available Cash, in the form of an increase in the Face Value at the Distribution Rate as of the last day of the respective quarter (each such distribution pursuant to clause (ii), an “Accrued Distribution”); provided, that, for each full quarter ending on or after the quarter in which the Commercial Operation Date occurs, the applicable rate for Accrued Distributions shall be at a rate per annum equal to 1% per annum above the Distribution Rate.

(b) Distributions shall accrue and be cumulative and shall be computed on the basis of a 360-day year comprised of four quarters of 90 days each. Accrued Distributions shall accrue and increase the Face Value of each outstanding Preferred Unit, whether or not declared by the Managing Member, in accordance with this Section 6.01.

Section 6.02 Distributions on Common Units.

(a) For each full quarter ending on or prior to the Commercial Operation Date, distributions on Common Units shall be paid from Net LNG Sales Proceeds on the Quarterly Distribution Date following such declaration by the Managing Member to the Members holding Common Units as they appear on the Schedule A at the close of business on the relevant record date for such distribution.

 

23


(b) Except as set forth in Section 6.02(a), prior to the eighth anniversary of the Closing Date, distributions on Common Units shall be paid from Available Cash on a quarterly basis on each Quarterly Distribution Date following such declaration by the Managing Member to the Members holding Common Units as they appear on the Schedule A at the close of business on the relevant Quarterly Distribution Date only for so long as at the time of any such distribution (i) the Company has redeemed for cash any Accrued Distributions that have previously cumulated and accrued and (ii) the requisite amount of distribution in cash on the Preferred Units is made on such Quarterly Distribution Date such that no Accrued Distribution is made or outstanding on such Quarterly Distribution Date.

(c) Following the eighth anniversary of the Closing Date but prior to the Redeemed in Full Date, except for Permitted Tax Distributions, (i) no distributions on Common Units shall be declared or paid and (ii) the Company shall use all Available Cash to effect Redemptions as soon as reasonably practicable and in any event on each Quarterly Distribution Date.

(d) Following the Redeemed in Full Date, distributions on Common Units shall be paid from Available Cash on a quarterly basis on each Quarterly Distribution Date following such declaration by the Managing Member to the Members holding Common Units as they appear on the Schedule A at the close of business on the relevant record date for such distribution.

Section 6.03 Distributions Upon Liquidation.

(a) Upon any (i) liquidation, dissolution or winding up of or (ii) bankruptcy, insolvency or other similar event in respect of the Company and its subsidiaries, whether voluntary or involuntary (a “Liquidation Event”), each Preferred Member shall be entitled to be paid in cash, before any amount shall be paid or distributed to the Common Members, an amount per Preferred Unit equal to the Redemption Price (such sum, the “Preferred Preference Amount”). If the amounts available for distribution by the Company to Preferred Members upon a Liquidation Event are not sufficient to pay the aggregate Preferred Preference Amount due to such Preferred Members, such Preferred Members shall share ratably in any distribution in connection with such Liquidation Event in proportion to the full respective preferential amounts to which they are entitled. After the prior payment in full of the Preferred Preference Amount in connection with a Liquidation Event, the remaining assets and funds of the Company available for distribution to its members, if any, shall be distributed among the Common Members in accordance with their Percentage Interest.

(b) The Preferred Members may elect to have treated as a Liquidation Event: (i) any merger, amalgamation or consolidation of the Company or Sponsor into or with another corporation (except one in which the holders of shares of the Company or Sponsor, as applicable, immediately prior to such merger, amalgamation or consolidation continue to hold at least a majority of the voting power of the shares of the surviving corporation), (ii) any sale, Transfer or license of all or substantially all of the assets of the Company or Sponsor, (iii) any sale or Transfer of 50% or more of the voting rights of the Company or Sponsor to a person or group as such terms are used in section 13(d) and 14(d) of the Securities Exchange Act of 1934 (each such event, described in clauses (i) through (iii) a “Change in Control Event”), or (iv) an IPO. If such election is made, the Company shall be required to redeem the Preferred Units for an amount per Preferred Unit equal to the Redemption Price, unless the Preferred Members agree otherwise in writing, and

 

24


all consideration payable to the Members of the Company in connection with any such merger, amalgamation or consolidation or IPO, or all consideration payable to the Company or Sponsor and distributable to Members, together with all other available assets of the Company (net of obligations owed by the Company that are senior to the Preferred Units), in connection with any such asset sale, Transfer or license or IPO, shall be, as applicable, paid by the purchaser to the holders of, or distributed by the Company in redemption (out of funds legally available therefor) of, the Preferred Units as if such transaction were a Liquidation Event. In furtherance of the foregoing, the Company and Sponsor shall take such actions as are necessary to give effect to the provisions of this Section 6.03(b), including without limitation, (i) in the case of a merger, amalgamation or consolidation of the Company, causing the definitive agreement relating to such merger, amalgamation or consolidation to provide for a rate at which the Preferred Units are converted into or exchanged for cash, new securities or other property which gives effect to the provisions of this Section 6.03(b), (ii) in the case of a merger, amalgamation or consolidation of Sponsor, redeeming the Preferred Units for a price per Preferred Unit which gives effect to the provisions of this Section 6.03(b), (iii) in the case of an asset sale, Transfer or license of the Company or Sponsor, redeeming the Preferred Units for a price per Preferred Unit which gives effect to the provisions of this Section 6.03(b), or (iv) in the case of an IPO, redeeming the Preferred Units for a price per Preferred Unit which gives effect to the provisions of this Section 6.03(b). The Company and Sponsor shall promptly provide to the Preferred Members such information concerning the terms of such merger, amalgamation consolidation or asset sale or IPO, and the value of the assets of the Company or Sponsor as may reasonably be requested by the Preferred Members. The amount deemed distributed to the Preferred Members upon any such transaction shall be the cash or the value of the property, rights or securities distributed to such Preferred Members by the Company or the acquiring person, firm or other entity, as applicable. Any election by the Preferred Members of the then outstanding Preferred Units pursuant to this Section 6.03(b) shall be made by written notice to the Company at least five (5) days prior to the closing of the relevant transaction.

Section 6.04 Optional Redemption.

(i) At any time and from time to time on or after the third anniversary of the Closing Date, the Company shall have the right, at its option, to elect to cause (and the Company shall cause, to the extent required by Section 6.02(c)) all or any portion of the outstanding Preferred Units (including Accrued Distributions) to be redeemed (each such redemption, a “Redemption”) for cash at a redemption price per Unit equal to:

(A) if the Redemption Date is on or prior to the [***] anniversary of the Closing Date, an amount equal to the product of the Base Return multiplied by [***];

(B) if the Redemption Date is after the [***] anniversary of the Closing Date and on or prior to the [***] anniversary of the Closing Date, an amount equal to the product of the Base Return multiplied by [***];

(C) if the Redemption Date is after the [***] anniversary of the Closing Date and on or prior to the [***] anniversary of the Closing Date, an amount equal to the product of the Base Return multiplied by [***];

 

25


(D) if the Redemption Date is after the [***] anniversary of the Closing Date, an amount equal to the Base Return;

(such amount, the “Redemption Price”).

(ii) Prior to any Redemption, the Company shall deliver to the Preferred Members a notice setting forth: (i) the date on which the redemption will occur (the “Redemption Date”), which shall be no earlier than five (5) Business Days after the date such notice is given; and (ii) with respect to each Preferred Member, the number of Preferred Units subject to redemption and the price to be paid to such Preferred Member in respect thereof.

(iii) The aggregate Redemption Price shall be payable in cash in immediately available funds to the respective Preferred Members on the Redemption Date.

ARTICLE VII.

TRANSFERS; PREFERENTIAL PURCHASE RIGHTS; EXEMPT TRANSFERS

Section 7.01 Restrictions on Transfer.

A Member shall have the right to Transfer its Units to any third party solely as provided in, and subject to, this Article VII and may not otherwise Transfer such Units. Except as set forth in Section 7.02, no Member may transfer any Units. Any Transfer not expressly permitted herein shall be void and of no effect.

Section 7.02 Permitted Transfers.

Notwithstanding anything to the contrary in Section 7.01, but subject to Section 7.03:

(a) a Member’s Units may be pledged to secure bona fide third party indebtedness and foreclosures (but excluding any subsequent Transfer) of such pledge may be made, and Permitted Upstream Transfers may be made;

(b) a Member may Transfer its Units to an Affiliate that is a direct or indirect wholly-owned subsidiary of such Member and that is not a Prohibited Person, provided that, in each case, such Affiliate shall assume the obligations of the Member and become a party to this Agreement in accordance with Section 7.03;

(c) a Preferred Member may Transfer its Preferred Units in connection with a Transfer of such Preferred Member’s Transfer of its Units (as such term is defined in CP Holdings LLC Agreement) in accordance with the terms of CP Holdings LLC Agreement to any Person who is not a Prohibited Person, as permitted by Section 7.03; and

(d) following expiration of the Lock-Up Period applicable to such Member, the Common Member may Transfer all or a portion of such Common Member’s Common Units to any person who is not a Prohibited Person, as permitted by Section 7.03.

 

26


Section 7.03 Transfer Procedures.

(a) Except pursuant to Transfers permitted by Section 7.02(a) or Section 7.02(b) or any foreclosure (but excluding any subsequent Transfer) of the pledge permitted by Section 7.02(a), no Member shall directly Transfer less than all of its Units or directly Transfer its Units to a Transferee that is not just one (1) Person (or Affiliated group of Persons) without the consent of the other Member, which may be withheld or conditioned at such Member’s sole discretion. Notwithstanding anything to the contrary, no direct Transfer of Units held by the Sponsor shall be made or effective (and any purported such Transfer shall be null and void) prior to the Redemption in Full Date.

(b) No Transfer may be made unless the Transferee (if a direct Transferee) (A) agrees in writing to be bound by the provisions of this Agreement as though it were a Member hereunder, and (B) unless waived by the Managing Member (in the case of a Transfer of the Preferred Units) or Majority Approval (in the case of a Transfer of the Common Units), causes to be delivered to the Company, at such Transferee’s sole cost and expense, a favorable opinion from legal counsel reasonably acceptable to the Managing Member (or a designee of the Managing Member to whom such authority has been delegated), to the effect that such Transfer does not violate or result in registration being required under any applicable United States federal securities law. In addition, such Transferee shall execute and deliver such other instruments and documents, in form and substance reasonably satisfactory to the Managing Member (including any instrument necessary to cause the Transferee to become a Member), as are reasonably requested by the Company in connection with such Transfer, and all other Members agree to execute and deliver such amendments hereto as are reasonably necessary to cause such Transferee to become a Member if requested by the Managing Member.

(c) Any Transfer that would cause a Person other than a wholly-owned subsidiary of Sponsor to obtain Control of the Company shall be void ab initio unless such Person shall not cause a “Change of Control” (as defined in the Project Financing Documents).

(d) Notwithstanding anything to the contrary herein, no Member, without Approval by the Managing Member, may Transfer all or any portion of its Units to any Person that is not a “United States person” within the meaning of Section 7701(a)(30) of the Code.

(e) Any Transfer that would cause (1) an Event of Default (as such term is defined in the Project Financing Documents), or other breach or default which (with notice, passage of time or otherwise) would give rise to the right of the Senior Lenders to exercise remedies under the Project Financing Documents, (2) a material breach by the Company or any of its subsidiaries, or termination, of any of the Key Project Contracts or (3) a material breach by CP Holdings or any of its Affiliates of the CP Holdings LLC Agreement shall be void ab initio.

(f) Any Transfer that would breach, violate or result in material non-compliance with any Governmental Authorization issued by FERC or the U.S. Department of Energy shall be void ab initio.

 

27


(g) The Members shall take, or shall cause Company to take, any actions as may be required to approve any Transfers of Common Units that are authorized in accordance with the provisions of this Article VII.

(h) The Company will reasonably (and use commercially reasonable efforts to cause its representatives to) cooperate in connection with any contemplated Transfer of Preferred Units (including, without limitation, participation in diligence and marketing efforts) at the sole expense of the Member Transferring such Units.

(i) The terms and conditions of any confidentiality agreement relating to a proposed Transfer by a Member are subject to the Company’s prior approval (not to be unreasonably withheld, conditioned or delayed) to the extent such confidentiality agreement does not protect the Confidential Information from further disclosure by such potential Transferee to the same extent as the Parties are obligated under Article IX; and each such Member agrees that it shall enforce and cause any such potential Transferee to abide by Article IX as if such proposed were directly bound thereby to the same extent as such member).

Section 7.04 Exit Cooperation.

(a) Following the expiration of the Lock-Up Period, if so requested by the Investor and Investor or its Affiliates have made a similar request under Section 7.05 of CP Holdings LLC Agreement, the Company and each other Member shall use commercially reasonable efforts to assist with and facilitate the marketing of the Transfer of any or all of the Preferred Units owned by the Investor or its Affiliates and any related Transfer transaction, including (in the case of the Company) by retaining an investment banker and legal counsel selected by the Investor (and reasonably acceptable to the Company) to market and implement the transaction to prospective investors that are permitted to acquire such Units in accordance with the terms hereof, making available reasonable due diligence information related to the Company and its subsidiaries and making its officers and personnel available to reasonably participate in connection with such efforts, provided, that neither the Company nor any Member nor any of their respective Affiliates shall be required to, or to cause any other Person to, waive any rights, make any concessions, incur any material liability or obligation, or amend or modify the terms of any contract or agreement in connection with the provision of the marketing assistance as contemplated hereby, and provided further, that the Company shall be entitled to establish reasonable due diligence processes and procedures so as to minimize the disruption on the ordinary operations of the Company and its subsidiaries. All fees, costs and expenses incurred by the Company, any non-participating Member or any of their respective Affiliates in connection with any transaction (whether or not consummated) arising from the exercise of the marketing rights described in this Section 7.04 (including the fees, costs and expenses of any investment banker or legal counsel engaged by the Company, any such non-participating Member or any of their respective Affiliates, but not including any internal costs or overhead incurred by the Company or any non-participating Member or any of their respective Affiliates in furtherance of this Section 7.04) shall be borne and paid by the Investor or its Affiliates.

(b) For the avoidance of doubt, Section 7.04(a) shall not limit the applicability of the other clauses of this Article VII.

 

28


(c) Notwithstanding anything herein to the contrary, if as of the date that is the ten (10) year anniversary of the Closing Date the Investor or any of its Affiliates hold any Units, the restrictions included in this Article VII (other than Section 7.03(b) or (e)) shall no longer apply to the Investor or any such Affiliate, but, for the avoidance of doubt the foregoing restrictions shall still apply to each other Member; provided, that this Section 7.04(c) shall not permit Investor or any such Affiliate to Transfer any Units to any Prohibited Person.

ARTICLE VIII.

GOVERNING LAW; DISPUTES

Section 8.01 Governing Law; Consent to Jurisdiction.

This Agreement shall be construed and enforced in accordance with and governed by the laws of the State of Delaware, without regard to choice of laws or conflict of laws principles that would require or permit the application of the laws of any other jurisdiction. Each of the Parties hereby irrevocably attorns and submits to the exclusive jurisdiction of the Court of Chancery of the State of Delaware (or in the event that such court does not have jurisdiction, to the exclusive jurisdiction of the U.S. District Court for the District of Delaware) respecting all matters relating to this Agreement and the rights and obligations of the Parties hereunder. Each of the Parties hereby agrees that service of any legal proceedings relating to this Agreement may be made by physical delivery thereof to its address provided in, or in accordance with, Section 11.01.

Section 8.02 Dispute Resolution.

(a) Except as otherwise provided herein, in the event of any dispute, claim or difference arising between the Parties in respect of the subject matter, the interpretation or the effect of this Agreement, such Parties (the “Involved Parties”) shall use their best endeavors to settle successfully such dispute, question or difference. To this effect, they shall consult and negotiate with each other, in good faith and understanding of their mutual interests, to reach an equitable solution satisfactory to the Involved Parties.

(b) If the Involved Parties do not reach a solution within a period of 30 days, then either party may submit such matter to the Court of Chancery of the State of Delaware (or in the event that such court does not have jurisdiction, to the U.S. District Court for the District of Delaware).

Section 8.03 Continuing Obligations.

Pending settlement of any dispute, the Parties shall abide by their obligations under this Agreement without prejudice to a final adjustment in accordance with an order of a court settling such dispute.

Section 8.04 Waiver of Jury Trial.

EACH MEMBER AND THE COMPANY HEREBY IRREVOCABLY WAIVES THEIR RESPECTIVE RIGHTS TO JURY TRIAL OF ANY DISPUTE BASED UPON OR ARISING OUT OF THIS AGREEMENT OR ANY OTHER AGREEMENTS RELATING HERETO OR ANY DEALINGS AMONG THEM RELATING TO THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY. The Parties each acknowledge that this waiver is a material inducement to enter into a business relationship and that they will continue to rely on the waiver in their related future dealings.

 

29


ARTICLE IX.

CONFIDENTIALITY; PUBLIC ANNOUNCEMENTS

Section 9.01 General.

Confidential Information shall not be disclosed by a Member or any of its Affiliates to any third party or the public without the prior written consent of Investor with respect to a disclosure by Sponsor or its Affiliates with respect to a disclosure by Investor or its Affiliates. Company shall not disclose Confidential Information except as permitted pursuant to Section 9.02 without the Approval of the Managing Member and the Investor.

Section 9.02 Exceptions.

The restriction imposed by Section 9.01 shall not apply to a disclosure of Confidential Information:

(a) to government agencies as required by the terms of any Governmental Authorizations;

(b) to direct or indirect equityholders, directors, officers, employees, partners (including limited partners), members, agents, and attorneys of a Party or an Affiliate of a Party who have a bona fide need to know such Confidential Information for purposes related to the disclosing Member’s interest in the Company and who have been advised of the confidential nature of such information;

(c) to any third party to whom the disclosing Member or its Affiliates lawfully contemplates a Transfer of all or any part of its interest in or to this Agreement and the Units (in accordance with the terms hereof);

(d) to a Governmental Authority or stock exchange or to the public which the disclosing Member or its Affiliates believes in good faith is required to be made by (i) any applicable Legal Requirements, (ii) any order, decree or directive of any competent judicial, legislative or regulatory body or authority applicable to the disclosing Party or its Affiliates or (iii) the rules of any relevant stock exchange or securities regulatory authority; provided that any obligation to file all or a portion of this Agreement with any securities regulatory authority shall be in accordance with Section 9.05;

(e) to (i) the Senior Lenders, (ii) any other actual or potential lenders, investors or underwriters of the disclosing Party or its Affiliates who have a bona fide need to be informed and (iii) any ratings agency that is providing or has been requested to provide a credit rating for the debt or preferred equity financing of the Project Company or any direct or indirect parent company of the Project Company or such Party or its Affiliates;

(f) to independent accountants, legal counsel or other technical or professional advisors engaged by a Party or its Affiliates for the purpose only of enabling such accountants,

 

30


legal counsel or other professional advisors to give appropriate advice in respect of matters arising under this Agreement related to operations of the Company or in respect of the normal business operations of the disclosing Party or its Affiliates;

(g) to any recognized merchant or investment banking firm engaged in giving advice to the disclosing Member or its Affiliates in connection with this Agreement or in respect of the normal business operations of the disclosing Member or its Affiliates; or

(h) in connection with any legal proceeding arising in connection with this Agreement, but any such disclosure shall be subject to such confidentiality procedures as may be reasonably requested by the disclosing Party and approved by the court.

In any case involving disclosure by a Member to which Section 9.02(a), (c), (d), (e) or (g) is applicable (subject to Section 9.03 with respect to disclosures required by applicable Legal Requirements), the disclosing Member shall, except as provided in Section 9.03, give notice to Sponsor with respect to any disclosure by Investor or its Affiliates or to Investor with respect to any disclosure by Sponsor or its Affiliates, in each case, at least seven days in advance of the making of such disclosure; provided, however, that such notice shall not be required with respect to information disclosed pursuant to Section 9.02 on a regular basis in the ordinary course of business or in connection with any Permitted Upstream Transfer. Such notice shall identify the Confidential Information to be disclosed and the recipient. As to any disclosure pursuant to Section 9.02(b), (c), (e), (f) or (g), only such Confidential Information as such third party shall have a legitimate business need to know shall be disclosed. As to any disclosure pursuant to Section 9.02(a) or (d), the disclosing Member shall disclose, or permit the disclosure of, only that portion of Confidential Information required to be disclosed and shall take all reasonable steps to preserve the confidentiality thereof. As to any disclosure pursuant to Section 9.02(c), (e) or (g), such third party shall first agree in writing to protect the Confidential Information from further disclosure to the same extent as the Parties are obligated under this Article IX. Notwithstanding the absence of a required written agreement, the disclosing Party shall be responsible for assuring that no unauthorized disclosure of information to be kept confidential pursuant to Section 9.01 is made by any Person receiving information pursuant to Section 9.02(b) or (f); provided that no Party shall be liable to any other Party for the fraudulent or negligent disclosure of Confidential Information by any such Person if the Party who seeks to take the benefit of this clause shall have taken reasonable steps to ensure the preservation and confidential nature of the information.

Section 9.03 Public Announcements.

Each Member shall, in advance of making, or any of its Affiliates making, a public announcement to a stock exchange or otherwise concerning this Agreement or the Company, advise the other Member of the text of the proposed report and provide the other Member with the opportunity to comment upon the form and content thereof before the same is issued; provided, however, that a Member or an Affiliate may make a public disclosure it believes in good faith is required by applicable Legal Requirements or any listing or trading agreement concerning the publicly traded securities of its direct or indirect parent (in which case the disclosing Member will use its reasonable best efforts to advise the other Member prior to the disclosure). If the other Member does not respond within 48 hours (excluding days that are not Business Days) or such lesser time specified as the maximum by the issuing Member or Affiliate, the announcement or

 

31


report may be issued. The final text of the same and the timing, manner and mode of release shall be the sole responsibility of the issuing Member who shall indemnify, defend and hold the other Member and its Affiliates, together with Company and Company, harmless in respect of any third party claims arising therefrom.

Section 9.04 Duration of Confidentiality.

The provisions of this Article IX shall apply during the term of this Agreement and for two years following termination of this Agreement and, as to any Member who Transfers its Units in accordance with Article VII, for two years following the date of such occurrence.

Section 9.05 Redacted Filings.

If a Member determines that this Agreement is or has become a material contract that is required to be filed pursuant to applicable securities laws or other Legal Requirement, such Member covenants:

(a) to file on EDGAR, as applicable, a redacted version of this Agreement in order not to prejudicially affect the interests of the Members; and

(b) to consult with the other Members on the preparation of such redacted Agreement prior to filing.

ARTICLE X.

TERMINATION

Section 10.01 Termination of Agreement.

(a) Termination. Except as otherwise provided herein, this Agreement shall continue in full force and effect without limit until the earlier of the following events:

(i) all the Members agree in writing to terminate this Agreement;

(ii) an effective resolution is passed or a binding order is made for the winding up of Company; or

(iii) there remains only one Member;

provided, however, that this Agreement shall cease to have effect with regards to any Person who ceases to hold directly or indirectly any Units pursuant to and in accordance with the terms of this Agreement save for any provisions hereof which, expressly or by implication, are to continue in full force and effect thereafter.

(b) Winding Up. If Company is wound up by way of a voluntary winding up Approved by the Managing Member, the Members shall procure a liquidator that is acceptable to each of the Members.

 

32


Section 10.02 Right to Data After Termination.

After termination of this Agreement by written agreement of all Parties, each Member shall be entitled to copies of all information related to the Company during the term of this Agreement not previously furnished to it, but a Member shall not be entitled to any such copies after any other termination for any other reason.

ARTICLE XI.

GENERAL PROVISIONS

Section 11.01 Notices.

All notices and other communications hereunder shall be in writing, and shall be effective (i) when personally delivered, including delivery by express courier service, (ii) on the day of receipt specified in any return receipt if it shall have been deposited in the mails or (iii) if transmitted by fax or electronic mail, on the date of transmission, in each case, to the addressee Party’s principal address stated below, whichever of the foregoing shall first occur; provided that any notice received after normal business hours at the place of delivery shall not be effective until the next Business Day at the place of delivery. Until otherwise specified by notice, the addresses for any notices shall be:

 

  (a)

If to Sponsor to:

Venture Global Calcasieu Pass Holding, LLC

1001 19th Street North

Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer

Fax No.:  [***]

Email:  [***]

 

 

with a copy to:

Latham & Watkins LLP

885 3rd Avenue

New York, NY 10022

Attention: [***]

 

  (b)

If to Investor, to:

Stonepeak Bayou Holdings II LP

c/o Stonepeak Infrastructure Partners

55 Hudson Yards

550 W 34th Street, 48th Floor

New York, NY 10001

Attention:   [***]

Email:    [***]

 

33


 

and:

Stonepeak Bayou Holdings II LP

c/o Stonepeak Infrastructure Partners

55 Hudson Yards

550 W 34th Street, 48th Floor

New York, NY 10001

Attention:   [***]

Email:   [***]

 

 

with a copy to:

Simpson Thacher & Bartlett LLP

425 Lexington Avenue

New York, NY 10017

Attention:   [***]

Email:   [***]

 

  (c)

If to Company to:

Calcasieu Pass Funding, LLC

1001 19th Street North

Suite 1500

Arlington, VA 22209

Attention: Managing Member

Fax No.: [***]

Email:    [***]

A Party may change its address from time to time by notice to the other Parties.

Section 11.02 Assignment.

No Party may Transfer all or any portion of its rights and/or obligations under this Agreement except in accordance with the applicable provisions hereof. Subject to the foregoing, this Agreement shall bind and inure to the benefit of the Parties and their respective successors and permitted assigns.

Section 11.03 Waiver.

Except as otherwise provided in this Agreement, failure on the part of any Party to exercise any right hereunder or to insist upon strict compliance by any other Party with any of the terms, covenants or conditions hereof shall not be deemed a waiver of such right, term, covenant or condition or limit the Party’s right thereafter to enforce any provision or exercise any right, power or remedy. No provision of this Agreement shall be construed to be a waiver by any of the Parties of any rights or remedies such Party may have against any other Party for failure to comply with the provisions of this Agreement and, except as expressly provided in this Agreement, no remedy or right herein conferred is intended to be exclusive of any other remedy or right, but every such remedy or right shall be cumulative and shall be in addition to every other remedy or right herein conferred or hereafter existing at law or in equity.

 

34


Section 11.04 Amendments.

This Agreement may not be amended or modified except by a written instrument signed by all of the Members, and Company shall be bound by any such amendment or modification. No Member shall be bound by any modification or amendment of this Agreement or waiver of any provision hereof unless such modification, amendment or waiver is set forth in a written instrument signed by each of the Members.

Section 11.05 Force Majeure.

The obligations of a Party shall be suspended to the extent and for the period that performance by such Party is prevented by any event of Force Majeure; provided that the affected Party shall give notice to the other Parties promptly, but in no event later than 30 days after the suspension of performance, stating in such notice the nature of the suspension, the reasons for the suspension and the expected duration of the suspension. The affected Party shall resume performance as soon as reasonably possible. Any time period during which performance must be achieved and as to which such performance is delayed because of Force Majeure shall be extended by a period equal to the period of suspension. Notwithstanding anything in this Section 11.05 to the contrary, an event of Force Majeure shall not excuse any payment obligation of any Party hereunder.

Section 11.06 Further Assurances.

Each Party shall take from time to time upon request of another Party, for no additional consideration, such actions and shall execute and acknowledge in form required by law for recording or registering with the proper Person and shall deliver to the requesting Party such notices, deeds or other instruments incorporating, referring to, or carrying out the provisions of this Agreement as the requesting Party may reasonably deem necessary in order to preserve or protect its interest under this Agreement or as may be reasonably necessary or convenient to implement and carry out the intent, provisions of and purpose of this Agreement.

Section 11.07 Survival of Terms and Conditions.

The provisions of this Agreement shall survive its termination to the full extent necessary for their enforcement and the protection of the Party in whose favor they run.

Section 11.08 Entire Agreement.

This Agreement, including all attached Schedules, and the Purchase Agreement contain the entire and final understanding of the Members and supersede all other prior agreements and understandings between the Members related to the subject matter of this Agreement.

 

35


Section 11.09 Severability.

Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. The validity of remaining sections, provisions, terms and parts of this Agreement shall not be affected by a court, administrative board or other proceeding of competent jurisdiction deciding that a provision, term or part of this Agreement is illegal, unenforceable, in conflict with any law or contrary to public policy. In such event the Parties shall undertake good faith efforts to amend this Agreement in order to replace such provision by a reasonable new provision or provisions which, as far as legally possible, shall approximate what the Parties intended by such original provision and the purpose thereof. Without limiting the generality of the foregoing, nothing in this Agreement shall require any Manager to act in contravention of the duties imposed on such Manager by applicable Legal Requirements.

Section 11.10 No Third-Party Beneficiary.

Except as specifically provided herein, no term or provision of this Agreement or the Schedules hereto is intended to be, or shall be construed to be, for the benefit of or enforceable by any Person, including any investment banker, broker or agent, and no such other Person shall have any right of cause of action hereunder. None of the provisions of this Agreement shall be for the benefit of, or shall be enforceable by, any creditor of the Company or any Member, other than the provisions of Section 7.02(a) which are for the benefit of, and may be enforced by a creditor of a Member.

Section 11.11 Time Is of the Essence.

A material consideration of the Members entering into this Agreement is that the other Members will make all contributions and other payments as and when due and will perform all other obligations under this Agreement in a timely manner. Except as otherwise specifically provided in this Agreement, time is of the essence for each and every provision of this Agreement.

Section 11.12 Limitation of Liability.

Each Party waives any claim for incidental or consequential damages hereunder, including damages for lost profits or for the speculative value or development potential of the business conducted by the Company.

Section 11.13 Counterparts.

This Agreement may be executed in any number of counterparts and by facsimile signatures, each of which when so executed and delivered shall be an original, but all the counterparts together shall constitute one and the same instrument.

[Signature Pages Follow]

 

36


IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed by their respective officers thereunto duly authorized as of the date first above written.

 

VENTURE GLOBAL CALCASIEU PASS HOLDING, LLC
By  

/s/ D. Michael Eberhardt

  Name: /s/ D. Michael Eberhardt
  Title: Chief Financial Officer

[Signature Page to Calcasieu Pass Funding LLCA]


CALCASIEU PASS FUNDING, LLC
By  

/s/ D. Michael Eberhardt

  Name: /s/ D. Michael Eberhardt
  Title: Chief Financial Officer

[Signature Page to Calcasieu Pass Funding LLCA]


STONEPEAK BAYOU HOLDINGS II LP

 

By: Stonepeak Associates III LLC, its general partner

 

By: Stonepeak GP Holdings III LP, its sole member

 

By: Stonepeak GP Investors III LLC, its general partner

 

By: Stonepeak GP Investors Manager LLC, its
managing member

By:  

/s/ Jack Howell

  Name: Jack Howell
  Title:  Senior Managing Director

[Signature Page to Calcasieu Pass Funding LLCA]


Schedule A

Members

[Omitted]

08-16-2019


Schedule B

Officers

[Omitted]

08-16-2019


Schedule C

Form of Certificates

[Omitted]

08-16-2019

Exhibit 10.65

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

LIMITED LIABILITY COMPANY AGREEMENT

among

CALCASIEU PASS HOLDINGS, LLC

and

THE MEMBERS NAMED HEREIN

dated as of

August 19, 2019

 


TABLE OF CONTENTS

 

         Page  

ARTICLE I. DEFINITIONS

     1  

Section 1.01

  Definitions      1  

Section 1.02

  Interpretation, Etc.      16  

Section 1.03

  Schedules      18  

ARTICLE II. ORGANIZATIONAL MATTERS

     18  

Section 2.01

  Formation      18  

Section 2.02

  Name      18  

Section 2.03

  Purpose      18  

Section 2.04

  Principal Place of Business; Foreign Qualifications      18  

Section 2.05

  Fiscal Year      19  

Section 2.06

  Registered Office; Registered Agent      19  

Section 2.07

  Powers      19  

Section 2.08

  Term      19  

Section 2.09

  Title to Property      19  

Section 2.10

  No Liability to Third Parties      19  

Section 2.11

  Other Business Opportunities; Independent Acquisition of Properties      19  

Section 2.12

  No Agency      20  

Section 2.13

  Priority of Agreements; Default Rules      21  

Section 2.14

  Liability Several      21  

Section 2.15

  Capacity of Members      21  

Section 2.16

  U.S. Tax Provisions      22  

ARTICLE III. MEMBERS

     22  

Section 3.01

  Members      22  

Section 3.02

  Units.      23  

Section 3.03

  Conversion      24  

Section 3.04

  Pre-Emptive Rights.      25  

Section 3.05

  Action by Members.      26  

Section 3.06

  Voting Rights      27  

Section 3.07

  Limitation of Liability of Members      27  

Section 3.08

  Unit Transfers      27  

Section 3.09

  No Right to Withdraw.      27  

Section 3.10

  Admission of New Members      28  

Section 3.11

  Exculpation and Indemnification      28  

ARTICLE IV. GOVERNANCE MATTERS

     29  

Section 4.01

  Board of Company      29  

Section 4.02

  Meetings of Board      32  


         Page  

Section 4.03

  Enhanced Approval      33  

Section 4.04

  Subsidiary Boards; Committees      37  

Section 4.05

  Agreement to Take Corporate Actions      38  

Section 4.06

  Expansion      38  

Section 4.07

  Contracts with Sponsor Member and its Affiliates.      39  

ARTICLE V. MANAGEMENT OF OPERATIONS

     39  

Section 5.01

  Officers      39  

Section 5.02

  Budget      40  

Section 5.03

  Information Rights      41  

ARTICLE VI. DISTRIBUTIONS

     42  

Section 6.01

  Distributions on Preferred Units      42  

Section 6.02

  Distributions on Common Units      43  

Section 6.03

  Distributions Upon Liquidation      43  

Section 6.04

  Project Company Distributions      44  

ARTICLE VII. TRANSFERS; PREFERENTIAL PURCHASE RIGHTS; EXEMPT TRANSFERS

     45  

Section 7.01

  Restrictions on Transfer.      45  

Section 7.02

  Permitted Transfers      45  

Section 7.03

  Right of First Offer      45  

Section 7.04

  Tag-Along Rights      47  

Section 7.05

  Transfer Procedures      48  

Section 7.06

  Exit Cooperation      49  

ARTICLE VIII. GOVERNING LAW; DISPUTES

     50  

Section 8.01

  Governing Law; Consent to Jurisdiction      50  

Section 8.02

  Dispute Resolution      50  

Section 8.03

  Continuing Obligations      50  

Section 8.04

  Waiver of Jury Trial      50  

ARTICLE IX. CONFIDENTIALITY; PUBLIC ANNOUNCEMENTS

     51  

Section 9.01

  General      51  

Section 9.02

  Exceptions      51  

Section 9.03

  Public Announcements      52  

Section 9.04

  Duration of Confidentiality      53  

Section 9.05

  Redacted Filings      53  

ARTICLE X. TERMINATION

     53  

Section 10.01

  Termination of Agreement      53  

Section 10.02

  Right to Data After Termination      54  

 

ii


         Page  

ARTICLE XI. GENERAL PROVISIONS

     54  

Section 11.01

  Notices      54  

Section 11.02

  Assignment      55  

Section 11.03

  Waiver      55  

Section 11.04

  Amendments      56  

Section 11.05

  Force Majeure      56  

Section 11.06

  Further Assurances      56  

Section 11.07

  Survival of Terms and Conditions      56  

Section 11.08

  Entire Agreement      56  

Section 11.09

  Severability      57  

Section 11.10

  No Third-Party Beneficiary      57  

Section 11.11

  Time Is of the Essence      57  

Section 11.12

  Limitation of Liability      57  

Section 11.13

  Counterparts      57  

SCHEDULES

 

Schedule A       Members
Schedule B       Tax Matters
Schedule C       Managers
Schedule D       Officers
Schedule E       Form of Certificates
Schedule F       Calculation of Conversion to Common Units
Schedule G       Initial Budget
Schedule H       Approved Sponsor Contracts

 

 

iii


LIMITED LIABILITY COMPANY AGREEMENT

This LIMITED LIABILITY COMPANY AGREEMENT (this “Agreement”) of Calcasieu Pass Holdings, LLC, a Delaware limited liability company (the “Company”), is entered into as of August 19, 2019 by and among the Company, Calcasieu Pass Funding, LLC, a Delaware limited liability company (“Sponsor Member”), and Stonepeak Bayou Holdings LP, a Delaware limited partnership (“Investor”).

WHEREAS the Company was formed by the filing of the Certificate of Formation with the Secretary of State of the State of Delaware pursuant to the Act (as defined below) on May 23, 2019;

WHEREAS, on or prior to the date hereof, Sponsor Member has contributed $549,500,000 to the Company in exchange for Class A Units (as defined below);

WHEREAS, Sponsor Member is a wholly-owned indirect subsidiary of Venture Global LNG, Inc. (“Sponsor”);

WHEREAS, on May 25, 2019, the Company, Sponsor and Investor entered into the Unit Purchase Agreement relating to the issuance and sale of the Preferred Units (as defined below);

AND WHEREAS Sponsor Member and Investor desire to establish certain rights and obligations between themselves as Members in accordance with the terms hereof.

NOW, THEREFORE, in consideration of the premises and the mutual agreements herein set forth, the receipt and sufficiency of which are hereby acknowledged, the Parties hereby agree as follows:

ARTICLE I.

DEFINITIONS

Section 1.01 Definitions.

As used in this Agreement, the following terms shall have the meanings given below.

Abandon” means any of the following:

 

  (a)

the abandonment, suspension or cessation of construction or operations of the Project, in each case, for a period in excess of 60 consecutive days (other than as a result of Force Majeure so long as the Project Company is diligently attempting to resume or restart the Project); provided that if this is not accompanied by a formal, public announcement by the Project Company (or any of its Affiliates) of its intentions as set forth in clause (ii) below, such abandonment, suspension or cessation shall not have occurred unless, within 45 days following notice to the Project Company requesting the Project Company to deliver a certificate to the effect that it will resume construction or operation as soon as is commercially reasonable, the Project Company has not delivered such certificate or resumed such activities or, if such certificate is delivered, the Project Company has nevertheless not resumed such activities within 90 days following receipt of such notice;


  (b)

a formal, public announcement by the Project Company (or any of its Affiliates) of a decision to permanently abandon, cease or indefinitely defer or suspend the Project for any reason; or

 

  (c)

the Project Company (or any of its Affiliates) shall make any filing with FERC giving notice of the intent or requesting authority to permanently abandon the Project for any reason.

Accrued Distribution” has the meaning set forth in the Sponsor Member LLC Agreement.

Act” means the Delaware Limited Liability Company Act.

Affiliate” means (and as applicable as part of its derivative “Affiliated” means), with respect to any Person, the following: (i) any other Person that directly or indirectly, through one or more intermediaries, Controls such Person and (ii) any other Person that is Controlled by or under common Control with such Person.

Agreement” has the meaning set forth in the preamble.

Approved by Company”, “Approved by the Board”, “Approval” or “Approved” means a proposal or action in respect of the Company that has been approved by the Board in accordance with Article IV (subject to and without limiting, in each case, any applicable requisite consent of any Member(s), to the extent otherwise expressly required hereunder).

Available Cash” means (without duplication) all unrestricted and distributable cash and cash equivalents of the Company and its subsidiaries (including the Project Company and Pledgor), including (to the extent unrestricted and distributable) the amount of Net LNG Sales Proceeds, less any portion thereof set aside by the Board in order to make regularly scheduled payments or mandatory prepayments on indebtedness and to maintain reasonably adequate reserves for operations or anticipated distributions of a Special Class A Distribution Amount or a Special Class B Distribution Amount as reasonably determined by the Board.

Board” means the board of managers of the Company.

Budget” means, with respect to each Fiscal Year, a budget for the Project Company, TCP and their respective subsidiaries which (x) sets out in reasonable detail all planned acquisitions, capital or operating expenditures and other investments, if any, and (y) includes forecasts prepared by Officers of income statements and cash flow statements on a quarterly basis for the following Fiscal Year.

Business Day” means a day other than Saturday, Sunday or statutory holiday on which commercial banks located in the city of New York, New York are open for business during normal banking hours.

 

2


Calendar Year” means the period of 12 consecutive months starting on the first day of January at 12:00 a.m., Eastern standard time, and ending on the immediately following 31st day of December at 11:59 p.m. midnight, Eastern standard time. If any activity or event that is to be performed or that is to occur during or in respect of any Calendar Year established herein begins after January 1st of such Calendar Year, the period covered shall be the period from the time of commencement of the action or event through December 31st of the year in which the time of commencement occurs.

Capital Contribution” means, subject to any limitations imposed by Legal Requirements, any contribution to the capital of the Company by a Member in respect of its Units in cash, property, the use of property, services or otherwise, whenever made.

Certificate of Formation” means the certificate of formation of the Company as filed with the Secretary of State of the State of Delaware, as may be amended from time to time.

Change in Control Event” has the meaning set forth in Section 6.03(b).

Claims” has the meaning set forth in Section 3.11(b).

Class A Units” has the meaning set forth in Section 3.02(b).

Class B Manager” means the Manager selected and appointed by the Members holding Preferred Units or Class B Units, as applicable, in accordance with Section 4.01(b)(i) or either of the Managers selected and appointed by the Members holding Preferred Units or Class B Units, as applicable, in accordance with Section 4.01(b)(ii), as the case may be.

Class B Units” has the meaning set forth in Section 3.02(b).

Closing Date” means the date on which the conditions precedent to the sale and purchase of the Preferred Units under the Purchase Agreement shall have been satisfied or waived, the Preferred Units shall have been issued hereunder and the purchase price therefor shall have been paid.

Code” means the United States Internal Revenue Code of 1986, as amended from time to time.

Commercial Operation Date” means the date on which: (a) each of the LNG Facility and the Lateral Pipeline have achieved “substantial completion” (or the equivalent) under the Facility EPC Agreements and the Pipeline EPC Agreement, respectively, including satisfactory completion of all commissioning and testing specified therein, and the LNG Facility has commenced operations in accordance with all performance guarantees; (b) all Project Costs due and payable have been paid, including any liquidated damages and final payments under Key Project Contracts (to the extent required by the Project Financing Documents), and all punch list and other remaining Project Costs, including any bonuses or other incentive payments owing to any counterparty, have been quantified and appropriate amounts have been set aside for the payment of such costs to the extent not paid; (c) each Foundation LNG SPA (together with each other Key Project Contract) and each Governmental Authorization then required for the operation of the Project shall be in full force and effect and no material default shall exist under any such

 

3


Key Project Contract or Governmental Authorization; (d) the Company shall have notified each buyer under its relevant Foundation LNG SPA that the LNG Facility has become commercially operable and “commercial operation” (or the equivalent) shall have been achieved under each Foundation LNG SPA within the required time period after such notice (upon which designated commercial volumes of LNG are required to be delivered and taken under, and in accordance with, each such Foundation LNG SPA, notwithstanding any delivery of commissioning volumes prior thereto); and (e) the construction loans under the Project Financing have converted to term loans in accordance with the Project Financing Documents and no default or event of default exists under the Project Financing Documents.

Common Member” has the meaning set forth in Section 3.01.

Common Units” has the meaning set forth in Section 3.02(b).

Company” has the meaning set forth in the preamble.

Confidential Information” means the terms of this Agreement and any other information concerning any matters affecting or relating to the business, operations, assets, results or prospects of the Company or its subsidiaries, including information regarding plans, budgets, processes, except to the extent that such information has already been publicly released (in a manner that does not violate or breach this Agreement).

Control” means (and as applicable as part of its derivatives “Controls” and “Controlled” means) possession, directly or indirectly, of the power to vote 50% or more of the voting power of such Person or to otherwise direct or cause the direction of the management or policies of a Person, whether through ownership of the voting power of such Person, by contract or otherwise.

Conversion Date” has the meaning set forth in Section 3.03.

Covered Persons” has the meaning set forth in Section 3.11(a).

Cure Date” has the meaning set forth in Section 4.01(b)(ii).

Default Rule” means a provision of the Act that would apply to the Company unless otherwise provided in, or modified by, this Agreement.

Distribution Rate” means:

 

  (a)

prior to the eighth anniversary of the Closing Date, a rate of 10.0% per annum;

 

  (b)

from and after the eighth anniversary of the Closing Date, a rate per annum equal to the sum of (i) 10.0% plus (ii) an additional 0.50% for every six-month period following such eighth anniversary, but shall in no event exceed 15.0% per annum.

Dollars”, “dollars” or “$” means currency of the United States of America unless otherwise specifically indicated.

 

4


Encumbrance” or “Encumbrances” means mortgages, charges, deeds of trust, security interests, pledges, liens, royalties, overriding royalty interests, preferential purchase rights or other encumbrances or burdens of any nature whether imposed by contract or operation of law.

Entity” means any corporation (including any non-profit corporation), company, limited liability company, limited duration company, general partnership, limited partnership, limited liability partnership, joint venture, joint stock association, estate, trust, cooperative foundation, union, syndicate, league, consortium, coalition, committee, society, firm or other enterprise, association, organization or entity of any nature recognized under the laws of any jurisdiction.

Emergency” means a sudden or unexpected event which causes or imminently risks causing (a) substantial damage to the Project or any material portion or component thereof, (b) death of or injury to any natural person, (c) damage to natural resources (including wildlife) or the environment or (d) material noncompliance by the Company or its subsidiaries with applicable Legal Requirement or the terms of any Key Project Contract or the Project Financing Documents, in each case, reasonably requiring immediate remedial action of the Company or any of its subsidiaries.

EPC Force Majeure” means a “Force Majeure” event under and as defined in any Facility EPC Agreement or the Pipeline EPC Agreement.

Face Value” means, with respect to Preferred Units, an initial value of $400,000,000 as may be increased pursuant to Section 6.01.

Facility EPC Agreements” means each of the following:

 

  (a)

the Engineering, Procurement and Construction Agreement, dated as of November 21, 2018, by and between the Project Company and Kiewit Louisiana Co., as supplemented by Limited Notice to Proceed, dated as of December 21, 2018 and as amended by Amendment No. 1 to Engineering, Procurement and Construction Agreement, dated as of July 9, 2019, by and between the Project Company and Kiewit Louisiana Co., as supplemented by Change Order No. 1, dated March 19, 2019 and Change Order No. 2, dated July 24, 2019, together with the Guaranty, dated as of November 21, 2018, by Kiewit Energy Group Inc. in favor of the Project Company;

 

  (b)

the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of September 25, 2018, by and between the Project Company and GE Oil & Gas, LLC, as supplemented by Limited Notice to Proceed, dated as of September 25, 2018, and Change Order No. 1, dated as of June 24, 2019, by and between the Project Company and GE Oil & Gas, LLC, as supplemented by the Letter Agreement re: UOP Pre-Treatment System, dated as of June 24, 2019, by and between the Project Company and GE Oil & Gas, LLC, and as further supplemented by the Letter Agreement re: Guaranteed Substantial Completion Dates dated as of August 12, 2019, by and between the Project Company and GE Oil & Gas, LLC and together with the Guaranty Agreement, dated as of September 28, 2018 by General Electric Company in favor of the Project Company;

 

5


  (c)

the Purchase Order Contract for the Sale of Power Island System, dated as of September 25, 2018, by and between the Project Company and GE Oil & Gas, LLC, as supplemented by Limited Notice to Proceed, dated as of February 5, 2019, and Change Order No. 1, dated as of June 24, 2019, by and between the Project Company and GE Oil & Gas, LLC, as supplemented by the Letter Agreement re: UOP Pre-Treatment System, dated as of June 24, 2019, by and between the Project Company and GE Oil and Gas, LLC and together with the Guaranty Agreement, dated as of September 28, 2018 by General Electric Company in favor of the Project Company;

 

  (d)

the Engineering and Procurement Agreement relating to the pre-treatment system for the Calcasieu Pass LNG export and liquefaction facility in Cameron Parish, Louisiana, dated as of December 21, 2018, by and between the Project Company and UOP LLC, as amended by Amendment No. 1 to Engineering and Procurement Agreement, dated as of June 28, 2019, and supplemented by Limited Notice to Proceed, dated as of December 21, 2018, and Limited Notice to Proceed No. 2, dated as of June 28, 2019, by and between the Project Company and UOP LLC;

 

  (e)

the Amended and Restated LNG Storage Tanks Engineering, Procurement and Construction Agreement, dated as of December 22, 2017, by and between the Project Company and CB&I LLC, as amended by Amendment No. 1 to Amended and Restated LNG Storage Tanks Engineering, Procurement and Construction Agreement, dated as of April 1, 2019, and Amendment No. 2 to Amended and Restated LNG Storage Tanks Engineering, Procurement and Construction Agreement, dated as of June 30, 2019, and supplemented by Anticipated LNTP, dated as of October 1, 2018, Limited Notice to Proceed No. 2, dated as of April 1, 2019, and Limited Notice to Proceed No. 3, dated as of June 30, 2019, by and between the Project Company and CB&I LLC;

 

  (f)

the Construction Agreement relating to Marine Works, dated as of January 24, 2017, by and between the Project Company and Weeks Marine, Inc., as amended by Amendment No. 1 to Construction Agreement, dated as of December 13, 2017, Amendment No. 2 to Construction Agreement, dated as of October 5, 2018, Amendment No. 3 to Construction Agreement, dated as of March 5, 2019, and Amendment No. 4 to Construction Agreement, dated as of June 28, 2019, Amendment No. 5 to Construction Agreement, dated July 3, 2019, and supplemented by Anticipated LNTP, dated as of October 5, 2018, and Limited Notice to Proceed No. 2, dated as of February 22, 2019, by and between the Project Company and Weeks Marine, Inc. and Notice to Proceed, dated as of July 3, 2019, as supplemented by the Letter Agreement, dated as of July 3, 2019, between the Project Company and Weeks Marine, Inc.; and

 

  (g)

the Construction Agreement relating to Storm Surge Wall, dated as of February 15, 2017, by and between the Project Company and Weeks Marine, Inc., as amended by Amendment No. 1 to Construction Agreement, dated as of December 13, 2017, Amendment No. 2 to Construction Agreement, dated as of October 5, 2018, Amendment No. 3 to Construction Agreement, dated as of March 5, 2019, and

 

6


  Amendment No. 4 to Construction Agreement, dated as of June 28, 2019, and supplemented by Anticipated LNTP, dated as of October 5, 2018, Limited Notice to Proceed No. 2, dated as of February 22, 2019, and Notice to Proceed, dated as of June 28, 2019, by and between the Project Company and Weeks Marine, Inc. as supplemented by the Letter Agreement, dated as of June 28, 2019, between the Project Company and Weeks Marine, Inc.

Facility Expansion” means an expansion of the Project (including, without limitation, the addition of one or more liquefaction blocks, trains, supporting facilities and/or addition of compression to, a looping project relating to or another expansion of the Lateral Pipeline); provided, however, that any increases or improvements in the capacity or specifications of the Project as a result of de-bottlenecking or similar optimization initiatives shall not be considered to be a Facility Expansion.

FERC” means the Federal Energy Regulatory Commission.

Force Majeure” means either an EPC Force Majeure or an LNG SPA Force Majeure.

Foundation LNG SPAs” means each of the following:

 

  (a)

LNG Sales and Purchase Agreement (FOB), dated as of January 19, 2016, by and between Shell NA LNG LLC and the Project Company, as amended by First Amendment to LNG Sales and Purchase Agreement (FOB), dated as of June 27, 2016, by Second Amendment to LNG Sales and Purchase Agreement (FOB), dated as of December 7, 2016, by Third Amendment to LNG Sales and Purchase Agreement (FOB), dated as of March 27, 2017, and by Fourth Amendment to LNG Sales and Purchase Agreement (FOB), dated as of February 28, 2018, as amended and restated by Amended and Restated LNG Sales and Purchase Agreement, dated as of April 4, 2018, by and between Shell NA LNG LLC and the Project Company, as amended by First Amendment to Amended and Restated LNG Sales and Purchase Agreement (FOB), dated as of August 10, 2018 and Second Amendment to Amended and Restated LNG Sales and Purchase Agreement (FOB), dated as of June 14, 2019;

 

  (b)

LNG Sales and Purchase Agreement (FOB), dated as of September 25, 2017, by and between Edison S.p.A. and the Project Company, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of February 28, 2018, Amendment No. 2 to LNG Sales and Purchase Agreement (FOB), dated as of June 13, 2018, Amendment No. 3 to LNG Sales and Purchase Agreement (FOB), dated as of December 10, 2018 and Amendment No. 4 to LNG Sales and Purchase Agreement (FOB), dated as of June 10, 2019, and supplemented by Waiver of Condition Precedent, dated September 4, 2018, by Edison S.p.A.;

 

  (c)

LNG Sales and Purchase Agreement (FOB), dated as of April 30, 2018, by and between Galp Energia E&P B.V. and the Project Company, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of December 20, 2018;

 

7


  (d)

LNG Sales and Purchase Agreement (FOB), dated as of May 17, 2018, by and between BP Gas Marketing Limited and the Project Company;

 

  (e)

LNG Sales and Purchase Agreement (FOB), dated as of August 14, 2018, by and between Repsol LNG Holding, S.A. and the Project Company, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of June 10, 2019;

 

  (f)

LNG Sales and Purchase Agreement (FOB), dated as of September 28, 2018, by and between Polskie Górnictwo Naftowe I Gazownictwo Spółka Akcyjna and the Project Company; and

 

  (g)

any Replacement SPA entered into by the Company in accordance with this Agreement.

GAAP” has the meaning set forth in Section 5.03(a)(i).

Governmental Authority” means any governmental authority, local authority or political subdivision of any of the foregoing, any multi-national organization or body, any agency, department, commission, board, bureau, court or other authority thereof or any quasi-governmental or private body having jurisdiction or entitled to exercise any executive, legislative, judicial, administrative, police, regulatory or taxing authority or power of any nature.

Governmental Authorization” means any permit, license, franchise, approval, certificate, consent, ratification, permission, confirmation, endorsement, waiver, certification, registration, transfer, qualification or other authorization issued, granted, given or otherwise made available by or under the authority of any Governmental Authority or pursuant to any Legal Requirement.

Independent Engineer” means Lummus Consultants International, and any successor nationally recognized engineering consultant to the Project serving in the role filled by Lummus Consultants International on the date of this Agreement.

Initial Capital Contribution” has the meaning set forth in Section 3.02(c).

Investment Fund” means any financial sponsor, investment fund, or any investment manager, administrator or advisor, or any similar firm or vehicle making financial investments in debt or equity securities or interests as part of the ordinary course of its business (in each case, including any alternative investment vehicles, parallel funds and parallel accounts, co-invest vehicles or other investment vehicles thereof), and any Affiliate thereof (excluding any such Affiliate that is a portfolio company, but for the avoidance of doubt including any such Affiliate that is a co-invest vehicle).

Investor” has the meaning set forth in the preamble.

Involved Parties” has the meaning set forth in Section 8.02(a).

 

8


IPO” means the initial sale of equity or equivalent securities of the Company, any of its subsidiaries or any successor to any of the foregoing (including pursuant to any restructuring, recapitalization or reorganization), to the public pursuant to an effective registration statement filed under the Securities Act (or any foreign reasonable equivalent).

Key Project Contract” means each of the following:

 

  (a)

each Facility EPC Agreement;

 

  (b)

the Pipeline EPC Agreement;

 

  (c)

each Foundation LNG SPA;

 

  (d)

the Firm Transportation Service Agreement dated July 10, 2019, between TCP and the Project Company;

 

  (e)

Interruptible Transportation Service Agreement dated July 10, 2019, between TCP and the Project Company;

 

  (f)

the Precedent Agreement, dated as of November 14, 2018, by and between Texas Eastern Transmission, LP, and the Project Company as superseded by the service agreement described therein;

 

  (g)

the Amended and Restated Precedent Agreement for Firm Natural Gas Transportation Service, dated as of December 21, 2018, by and between ANR Pipeline Company and the Project Company, as superseded by the service agreement described therein;

 

  (h)

the Guarantee, dated as of February 4, 2016, issued by Shell Oil Company, in favor of the Project Company, as amended by First Amendment to Guarantee, dated as of March 5, 2018;

 

  (i)

the Guarantee, dated as of May 17, 2018, by BP International Limited in favor of the Project Company;

 

  (j)

the Guarantee, dated as of May 18, 2018, by Galp Energia, SGPS, SA in favor of the Project Company;

 

  (k)

the Guarantee, dated as of August 18, 2018, by Repsol Exploracion, S.A. in favor of the Project Company;

 

  (l)

any other guarantee delivered under a Foundation LNG SPA;

 

  (m)

the long-term service agreement to be entered into between the Project Company and GE Oil & Gas, LLC in substantially the same form approved by the Investor following the date hereof, such consent not to be unreasonably withheld;

 

9


  (n)

the Field Services Agreement, dated as of August 14, 2019, by and between the Project Company and GE Oil & Gas, LLC;

 

  (o)

the Technical Advisor Services Agreement, dated as of July 29, 2019, by and between the Project Company and UOP LLC;

 

  (p)

the Amended and Restated Ground Lease Agreement, dated as of June 20, 2019, by and between the Project Company and Henry Venture, LLC;

 

  (q)

the Amended and Restated Ground Lease Agreement, dated as of July 15, 2019, by and between the Project Company and JADP Venture, LLC;

 

  (r)

any replacement of any existing agreement described in (a) through (q) above and approved in accordance with this Agreement; and

 

  (s)

any counterparty guarantee or other credit support of any of the foregoing.

Lateral Pipeline” has the meaning set forth in the definition of Lateral Pipeline Project.

Lateral Pipeline Project” means the development, design, financing, engineering, procurement, construction, installation, tying-in, testing, commissioning, completion, ownership, insurance, operation and maintenance of a 42-inch diameter, approximately 24-mile long natural gas pipeline (the “Lateral Pipeline”) that is being developed by TCP and that will extend to the LNG Facility from interconnection points within the vicinity of Grand Cheniere Station in Cameron Parish, Louisiana.

Legal Requirement” means any law, statute, ordinance, decree, requirement, order, treaty, proclamation, convention, rule or regulation (or interpretation of any of the foregoing) of any Governmental Authority, any agreement with a Governmental Authority and the terms of any Governmental Authorization.

Liquidation Event” has the meaning set forth in Section 6.03(a).

Liquidation Price” means an amount equal to the Face Value, as increased by any accrued but unpaid distributions thereon.

LNG Facility” means the 10.0 MTPA (nameplate) natural gas liquefaction and LNG export facility being developed by the Project Company in Cameron Parish, Louisiana, including: (i) nine modular approximately 1.25 MTPA natural gas liquefaction blocks, (ii) two 200,000 cubic meter cryogenic LNG storage tanks, (iii) a marine terminal with two ship-loading berths for LNG vessels up to 185,000 cubic meters in capacity, (iv) a 620 MW onsite combined cycle gas turbine power plant, (v) a natural gas pretreatment system capable of treating approximately 2,024 MMSCFD of natural gas, (vi) a perimeter wall currently anticipated to be 31 feet high on the north, east, and south sides of the terminal site and a 26.5 feet high berm on the west side of the terminal site and associated surge protection walls, (vii) administration and operating and maintenance buildings, (viii) all required utilities, instruments, control systems and piping, and (ix) all associated real property interests (including any leased real property).

 

10


LNG Facility Project” means the development, design, financing, engineering, procurement, construction, installation, tying-in, testing, commissioning, completion, ownership, insurance, operation and maintenance of the LNG Facility.

LNG SPA Force Majeure” means a “Force Majeure” event under and as defined in any Foundation LNG SPA.

Lock-Up Period” means, (a) in respect of any Member other than Sponsor Member, the period commencing on the date hereof and ending on the first year anniversary of the Commercial Operation Date, and (b) in respect of Sponsor Member, the period commencing on the date hereof and ending on the first year anniversary of the Commercial Operation Date or, solely in respect of any direct Transfer, the Redemption Date, if later than such first year anniversary.

Manager” means a member of the Board.

Member Indemnitors” has the meaning set forth in Section 3.11(d).

Members” means Sponsor Member and Investor as owners of the Units, and “Member” means either one of them.

MMSCFD” means million standard cubic feet per day.

MTPA” means million tonnes of LNG per annum.

Net LNG Sales Proceeds” means (without duplication) the total amounts received by the Company from the sale by the Company and its subsidiaries of LNG produced and loaded at the LNG Facility prior to the Commercial Operation Date (such period, the “Pre-Commercial Production Period”), less: (1) the aggregate amount of costs incurred by the Company and its subsidiaries in respect of all natural gas purchased to operate the LNG Facility or a portion thereof and produce LNG during the Pre-Commercial Production Period; (2) the aggregate amount incurred by the Company and its subsidiaries during the Pre-Commercial Production Period in respect of all natural gas transportation capacity; (3) the aggregate amount of costs incurred by the Company and its subsidiaries during the Pre-Commercial Production Period to operate the LNG Facility, including operating expenses, labor, consumables, port services, line handling charges, insurance costs, debt service, and sales and use, property, ad valorem or similar taxes; (4) the Company’s and its subsidiaries’ estimated income taxes on the Net LNG Sales Proceeds; (5) amounts paid by the Company and its subsidiaries under each LNG sales agreement entered into with respect to LNG sold during the Pre-Commercial Production Period, such as demurrage or other charges; (6) any amounts required to pay any incentive payments to any contractor, including payments of a portion of revenues; (7) working capital costs; and (8) general and administrative overhead for intercompany services during the Pre-Commercial Production Period, and after giving effect to any allocation of such proceeds to pay for Project Costs pursuant to the Project Financing Documents.

New Subscriber” has the meaning set forth in Section 3.04(d).

Non-Transferring Member” has the meaning set forth in Section 7.03(b).

 

11


Non-Transferring Member Offer” has the meaning set forth in Section 7.03(b).

Officer” has the meaning set forth in Section 5.01(a).

Party” means each of the Members and the Company individually, and “Parties” means the Members and the Company, collectively.

Percentage Interest” means, as of any date of determination, as to any Common Member with respect to Common Units the quotient obtained by dividing (a) the number of Common Units held by such Member by (b) the total number of outstanding Common Units. For avoidance of doubt, the Percentage Interest with respect to any Preferred Member shall at all times be zero.

Permitted Expansion” has the meaning set forth in Section 4.06.

Permitted Upstream Transfer” means, (a) with respect to any Member that is or is Controlled by, or otherwise directly or indirectly owned in whole or in part by, an Investment Fund, any direct or indirect Transfer or issuance of equity ownership (i) in such Investment Fund that is generally passive (which, for purposes of this definition shall include equity ownership that does not (A) have the right to vote with respect to, or otherwise Control, the day-to-day management activities of such Investment Fund or (B) have more than customary limited rights or ability to participate in any decision-making with respect to any action or exercise any right of a Member under this Agreement, except for such rights as are generally provided under agreements generally applicable to (x) the investors in such Investment Fund or (y) investments by such Investment Fund), (ii) in the investment manager, administrator or advisor or other Person providing management, administrative or advisory services to such Investment Fund in the ordinary course of its and such Investment Fund’s business, or (iii) to such Investment Fund and (b) with respect to any Member, (i) any offering of equity securities of such Member, or of any Person directly or indirectly having equity ownership of such Member, to the public pursuant to an effective registration statement filed under the Securities Act (or any foreign reasonable equivalent), (ii) any Transfer of equity securities of such Member, or of any Person directly or indirectly having equity ownership of such Member, that are listed on a national securities exchange and registered under the Securities Exchange Act of 1934 (or any foreign applicable law), (iii) any Transfer of equity securities of Sponsor and (iv) any Transfer of equity ownership of Sponsor Member in accordance with the Sponsor Member LLC Agreement, provided, in each case of (a) and (b) above, that the transferee is not a Prohibited Person.

Person” means any individual (including a personal representative), trust, Entity or Governmental Authority.

PIK Distribution” has the meaning set forth in Section 6.01(a).

PIK Units” has the meaning set forth in Section 6.01(a).

Pipeline EPC Agreement” means the Pipeline Construction Agreement, dated as of January 23, 2019, by and between TPC and WHC, LLC, as amended by Amendment No. 1 to Pipeline Construction Agreement, dated as of June 28, 2019, and supplemented by LNTP No. 1 dated as of January 24, 2019 and LNTP No. 2 dated as of January 25, 2019, Change Order No. 1, dated as of June 13, 2019, Change Order No. 2, dated as of June 14, 2019, Change Order No. 3, dated as of July 19, 2019, and Full Notice to Proceed, dated as of June 28, 2019, by and between TCP and WHC, LLC.

 

12


Pledgor” means Calcasieu Pass Pledgor, LLC, a Delaware limited liability company and a direct wholly-owned subsidiary of the Company.

Pre-Emptive Allocation” has the meaning set forth in Section 3.04(a).

Pre-Emptive Right Holder” has the meaning set forth in Section 3.04(a).

Preferred Member” has the meaning set forth in Section 3.01.

Preferred Preference Amount” has the meaning set forth in Section 6.03(a).

Preferred Units” has the meaning set forth in Section 3.02(b).

Prohibited Person” means any Person (other than Investor or Sponsor Member) that (i) is a foreign national oil or gas company, (ii) together with all of its Affiliates (taken as a whole) is primarily engaged in the business of developing, owning, or operating a greenfield national gas liquefaction project located in North America or an LNG export terminal located in North America; provided that this subpart (ii) shall not include Investment Funds investing in portfolio companies that qualify as Prohibited Persons pursuant to this subpart (ii); and provided, further, that such Person shall have entered into appropriate confidentiality arrangements and otherwise implemented and shall maintain internal institutional information barriers to prevent the disclosure to and use of the information of the Company and its Affiliates in respect of, for the benefit of or by such portfolio companies, (iii) is (or has any Affiliate, excluding portfolio companies, that is) engaged in any material litigation against the Company, its subsidiaries, the other Members or any of their respective Affiliates, (iv) any Investment Fund whose investment mandate is primarily to make financial investments in distressed equity or distressed debt securities (“Vulture Funds”), or any Affiliate of any such Vulture Fund that is reasonably identifiable based on the name of such Affiliate; provided, that this clause (iv) shall not include Affiliated Investment Funds, or portfolio companies or other Affiliates, of Vulture Funds, that do not have an investment mandate that is primarily to make financial investments in distressed equity or distressed debt securities so long as such Person shall have entered into appropriate confidentiality arrangements and otherwise implemented and shall maintain internal institutional information barriers to prevent the disclosure to and use of the information of the Company and its Affiliates in respect of, for the benefit of or by such Vulture Fund, or (v) is (or has any Affiliate that is) subject to and will cause the Company or any of its subsidiaries to become subject to sanctions, counterterrorism, anti-money laundering or criminal actions or civil complaints predicated on fraud, corruption or material securities law violations, or any laws or proceedings similar to the foregoing.

Project” means the LNG Facility Project or the Lateral Pipeline Project, individually or collectively.

Project Company” means Venture Global Calcasieu Pass, LLC, a Delaware limited liability company and an indirect wholly-owned subsidiary of the Company.

 

13


Project Costs” means all costs of acquiring, leasing, designing, engineering, procuring, purchasing, developing (including costs incurred in connection with preparing for and implementing a Project Financing), optioning, permitting, insuring, constructing, installing, commissioning, testing and starting-up (including costs relating to all equipment, site preparation, materials, spare parts, gas, transportation, pre-commercial operation operating costs and labor for) the Project, together with financing costs, including interest during construction and reserves.

Project Financing” means all Project level debt financing for the construction, operation and maintenance of the Project to be obtained by the Project Company and/or TCP from one or more Senior Lenders.

Project Financing Documents” means the documents evidencing or setting forth the terms and conditions of the Project Financing.

Qualifying LNG SPA” means a LNG sales and purchase agreement (FOB) entered into by the Project Company in accordance with the Project Financing Documents having (i) a contract term in excess of one (1) year and (ii) an average fixed facility charge (on a per MMBtu basis) sold by the Company and its subsidiaries during any Calendar Year after the Commercial Operation Date equal to $[***]/MMBtu or greater.

Quarterly Distribution Date” means the distribution date established by the Board as promptly as practicable following the last day of each calendar quarter (which shall, in any case, occur no later than thirty (30) days following the last day of such calendar quarter).

Reasonable and Prudent Operator” means a Person seeking in good faith to perform its contractual obligations, and in so doing, and in the general conduct of its undertaking, exercising that degree of skill, diligence, prudence and foresight which would reasonably and ordinarily be expected from a skilled and experienced operator, complying with all applicable international standards (including International LNG Terminal Standards (as such term is defined in a Foundation LNG SPA)) and practices and regulations and Governmental Authorizations, engaged in the same type of undertaking under the same or similar circumstances and conditions.

Redeemable Preferred Unit Holders” means the Redeemable Preferred Unit purchasers party to the Redeemable Preferred Unit Purchase Agreement and any assignee of such person’s interest in the Redeemable Preferred Units pursuant to the Sponsor Member LLC Agreement.

Redeemable Preferred Unit Purchase Agreement” means the Unit Purchase Agreement, dated as of May 25, 2019, by and among Sponsor, Sponsor Member and the purchaser party thereto.

Redeemable Preferred Units” means the Redeemable Preferred Units issued by Sponsor Member pursuant to the terms of the Sponsor Member LLC Agreement.

Redemption Date” means the date on which all of the outstanding Redeemable Preferred Units have been redeemed in full pursuant to the terms of the Sponsor Member LLC Agreement.

 

14


Related Party” means any Member or any of their respective Affiliates, or any other Person who does not deal at arm’s length with the Company, excluding any wholly-owned subsidiary of the Company.

Replacement SPA” has the meaning set forth in Section 4.03(a)(xviii)(3).

ROFO Notice” has the meaning set forth in Section 7.03(b).

Securities Act” means the Securities Act of 1933, as amended.

Self-Executing Action” has the meaning set forth in Section 4.07(a).

Senior Lenders” means the commercial banks and other institutional lenders (including any such lenders purchasing debt securities of the Project Company and/or TCP) that are party to the Project Financing, together with any agent or trustee therefor.

Special Class A Distribution Amount” means, in the event that the average fixed facility charge (on a per MMBtu basis) of Uncontracted Nameplate Capacity sold by the Company and its subsidiaries during any Calendar Year after the Commercial Operation Date is greater than $[***]/MMBtu (such amount, the “Uncontracted Ceiling Amount”), an amount equal to (a)(i) the average fixed facility charge (on a per MMBtu basis) of such Uncontracted Nameplate Capacity for such Calendar Year minus (ii) the Uncontracted Ceiling Amount multiplied by (b) the amount of volumes utilizing Uncontracted Nameplate Capacity sold by the Company and its subsidiaries during such Calendar Year multiplied by (c) the aggregate Percentage Interest held by the Members holding Class B Units.

Special Class B Distribution Amount” means in the event that the average fixed facility charge (on a per MMBtu basis) of Uncontracted Nameplate Capacity sold by the Company and its subsidiaries during any Calendar Year after the Commercial Operation Date is less than $[***]/MMBtu (such amount, the “Uncontracted Floor Amount”), an amount equal to (a) (i) the Uncontracted Floor Amount minus (ii) the average fixed facility charge (on a per MMBtu basis) of such Uncontracted Nameplate Capacity for such Calendar Year multiplied by (b) the amount of volumes utilizing Uncontracted Nameplate Capacity sold by the Company and its subsidiaries during such Calendar Year multiplied by (c) the aggregate Percentage Interest held by the Members holding Class B Units.

Specified Covered Persons” has the meaning set forth in Section 3.11(d).

Sponsor” has the meaning set forth in the recitals.

Sponsor Contract” means any contract or agreement between the Company or any of its subsidiaries, on the one hand, and Sponsor, Sponsor Member (or other holder or Affiliated group of holders of at least fifty (50%) of the outstanding Class A Units) or any Affiliate thereof, on the other hand.

Sponsor Member” has the meaning set forth in the preamble.

 

15


Sponsor Member LLC Agreement” means the limited liability company operating agreement of the Sponsor Member attached as Exhibit A to the Redeemable Preferred Unit Purchase Agreement.

Step-In Right” has the meaning set forth in Section 4.01(b)(ii).

Tag Price” has the meaning set forth in Section 7.04(a).

Tag-Along Member” has the meaning set forth in Section 7.04(a).

Tag-Along Notice” has the meaning set forth in Section 7.04(a).

Tag-Along Right” has the meaning set forth in Section 7.04(a).

Tag-Along Sale” has the meaning set forth in Section 7.04(a).

Tag-Along Transferee” has the meaning set forth in Section 7.04(a).

TCP” means TransCameron Pipeline, LLC, a Delaware limited liability company and an indirect wholly-owned subsidiary of the Company.

Transfer” (a) when used as a verb, means, directly or indirectly, to sell, grant, assign, create an Encumbrance on, pledge, charge or otherwise convey, or dispose of or commit to do any of the foregoing (and “Transferred” shall have the correlative meaning) and (b) when used as a noun, means a direct or indirect sale, grant, assignment, Encumbrance, pledge, charge, conveyance or other disposition (and “Transferor” and “Transferee” shall have the correlative meaning). For avoidance of doubt, any sale, assignment, or other transfer of any part or all of Investor by any parent entity of Investor shall constitute a Transfer.

Transferring Member” has the meaning set forth in Section 7.03(b).

Uncontracted Nameplate Capacity” means the portion of the 10.0 MTPA nameplate liquefaction capacity of the LNG Facility that has not been sold by the Project Company pursuant to a Foundation LNG SPA or a Qualifying LNG SPA on or after the Commercial Operation Date.

Unit Purchase Agreement” means that certain unit purchase agreement dated as of May 25, 2019 by and among Investor, Sponsor and the Company.

Units” means the units into which the interests in the Company are divided.

Vote” has the meaning set forth in Section 4.02(e).

Vulture Funds” has the meaning set forth in the definition of Prohibited Person.

Section 1.02 Interpretation, Etc.

This Agreement is the result of negotiations among the Parties, and the terms and provisions hereof (except where otherwise defined or the context otherwise requires) shall be construed in accordance with their usual and customary meanings. The captions or headings of

 

16


sections or subsections of this Agreement are for purposes of reference only and shall not limit or define the meaning of any provision of this Agreement. Insofar as is permissible under applicable Legal Requirements, the Parties hereby waive the application of any rule of law that ambiguous or conflicting terms or provisions should be construed against the Party who (or whose attorney) prepared the executed agreement or any earlier draft of the same. Any of the terms defined herein may, unless the context otherwise requires, be used in the singular or the plural, depending on the reference. References herein to any Section or Schedule shall be to a Section or Schedule, as the case may be, hereof unless otherwise specifically provided. The use herein of the word “include” or “including”, when following any general statement, term or matter, shall not be construed to limit such statement, term or matter to the specific items or matters set forth immediately following such word or to similar items or matters, whether or not non limiting language (such as “without limitation” or “but not limited to” or words of similar import) is used with reference thereto, but rather shall be deemed to refer to all other items or matters that fall within the broadest possible scope of such general statement, term or matter. The phrases “directly or indirectly” or “direct or indirect”, when used in the context of ownership, holdings, Control, Transfer, investment or acquisition include ownership, holdings, Control, Transfer, investment or acquisition, as applicable, through a chain of direct or indirect beneficial ownership or Control of one or more Persons. Where any provision in this Agreement refers to Transfers by any Person, such provision will be applicable whether such Transfer is made directly by such Person or by any Person directly or indirectly owning or holding any equity interests in such Person (it being understood and agreed, for the avoidance of doubt, that the provisions of this Agreement relating to any Transfer by any Member or any Transfer of the equity interests then owned by any Member shall be deemed to also apply to any Transfer of any equity interests in any Person directly or indirectly holding any equity interests in such Member). As used herein, the terms “portfolio company” and “co-invest vehicle” shall have the meanings commonly ascribed to such terms in the private equity industry. The terms “lease” and “license” shall include “sub-lease” and “sub-license”, as applicable. In this Agreement in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each mean “to but excluding”. Unless the context otherwise expressly requires, the word “or” shall not be exclusive and shall have the inclusive meaning implied by “and/or”. References in this Agreement to any Person shall mean and be a reference to such Person and its successors and permitted assigns (including in the case of any Member, such Member’s direct Transferees in respect of any Units directly Transferred in accordance with this Agreement). References in this Agreement to any agreement or contract, unless otherwise specified, shall mean and be a reference to such agreement or contract as amended, amended and restated, supplemented or otherwise modified from time to time in accordance with its terms. References in this Agreement to any Person shall mean and be a reference to such Person and its successors and permitted assigns (including in the case of any Member, such Member’s direct Transferees to the extent permitted under this Agreement). Where the term “subject to applicable Legal Requirements” is used, any applicable Legal Requirement shall govern or limit the referenced matter or action except to the extent that such Legal Requirement can be waived or overridden by agreement, in which case such Legal Requirement shall be deemed to have been waived and overridden by this Agreement to the extent that terms hereof conflict with such Legal Requirement within the limits of such permitted waiver or override. If and to the extent there is such a conflict which cannot be avoided, the Parties will work together in good faith using all available legal means (within reason) to carry into effect the intent of the Parties as evidenced by this Agreement.

 

17


Section 1.03 Schedules.

The following Schedules are attached to and form part of this Agreement:

 

Schedule A

         

Members

Schedule B

         

Tax Matters

Schedule C

         

Managers

Schedule D

         

Officers

Schedule E

         

Form of Certificates

Schedule F

         

Calculation of Conversion to Common Units

Schedule G

         

Initial Budget

Schedule H

         

Approved Sponsor Contracts

ARTICLE II.

ORGANIZATIONAL MATTERS

Section 2.01 Formation.

The Company was formed on May 23, 2019 pursuant to the Act by the filing of the Certificate of Formation with the Secretary of State of the State of Delaware.

Section 2.02 Name.

The name of the Company is “Calcasieu Pass Holdings, LLC”. All business of the Company will be conducted in such name or such other name as is Approved by the Board.

Section 2.03 Purpose.

The purpose of the Company shall be to engage in any lawful business, purpose or activity that may be engaged in by a limited liability company organized under the Act.

Section 2.04 Principal Place of Business; Foreign Qualifications.

The principal place of business of the Company shall be located at such location as may hereafter be determined by the Board. The location of the Company’s principal place of business may be changed by the Board from time to time in accordance with the then applicable provisions of the Act and any other applicable Legal Requirements. The Board may file or cause to be filed for recordation in the proper office or offices in each other jurisdiction in which the Company is formed or qualified, such certificates to establish, continue or terminate the qualification of the Company as a foreign limited liability company in all such jurisdictions in which the Company may conduct business.

 

18


Section 2.05 Fiscal Year.

The fiscal year for the Company shall be the Calendar Year.

Section 2.06 Registered Office; Registered Agent.

The address of the registered office of the Company as of the date of this Agreement is Corporation Trust Center, 1209 Orange Street, Wilmington, Delaware 19801. The registered agent of the Company on the date of this Agreement is The Corporation Trust Company. The Board may designate another registered agent or registered office from time to time in accordance with the then applicable provisions of the Act and any other applicable Legal Requirements.

Section 2.07 Powers.

The Company shall have the power and authority to take any and all actions that are necessary, appropriate, advisable, convenient or incidental to, or for the furtherance of, the purposes set forth in Section 2.03.

Section 2.08 Term.

The term of the Company commenced on the date of the initial filing of the Certificate of Formation with the Secretary of State of the State of Delaware and shall continue in perpetuity, unless sooner terminated in accordance with Article X or the Act.

Section 2.09 Title to Property.

All real and personal property owned or leased by the Company shall be owned or leased by the Company as an entity and no Member shall have any ownership or leasehold interest in such property in its individual name, and each Member’s interest in the Company shall be personal property for all purposes. Except as otherwise provided in this Agreement, the Company shall hold all of its real and personal property in the name of the Company and not in the name of any Member.

Section 2.10 No Liability to Third Parties.

The debts, obligations and liabilities of the Company, whether arising in contract, tort or otherwise, shall be solely the debts, obligations and liabilities of the Company, and no Member, Manager or officer shall be obligated personally for any such debt, obligation or liability of the Company solely by reason of being a Member or acting as a Manager or officer.

Section 2.11 Other Business Opportunities; Independent Acquisition of Properties.

Subject to the express terms of Section 4.06 but otherwise notwithstanding anything to the contrary in this Agreement or the Act, the doctrine of corporate opportunity, or any analogous doctrine, shall not apply to either Member or to any Manager. Except as expressly provided in this Agreement, each Member shall have the right independently to engage in and receive full benefits from business activities, whether or not competitive with operations conducted hereunder, without consulting the other Member. Neither Sponsor Member nor any Manager appointed by Sponsor

 

19


Member shall have any duty to the Company or any Member by reason of this Agreement to present any particular corporate, business or investment opportunity (including any opportunity with respect to the sale and purchase of LNG) to the Company or any Member, even if such opportunity is of a character that, if presented to the Company, could be taken by the Company or any of its subsidiaries, and any purported failure will not be deemed to be a breach of this Agreement, the Act or any other applicable law, and each Sponsor Member shall continue to have the right to take for its own accounts or as a partner, shareholder, fiduciary or otherwise, or to recommend to others, any such particular opportunity. Neither Investor nor any Manager appointed by Investor shall have any duty to the Company or any Member by reason of this Agreement to present any particular corporate, business or investment opportunity to the Company or any Member, even if such opportunity is of a character that, if presented to the Company, could be taken by the Company or any of its subsidiaries, and any purported failure will not be deemed to be a breach of this Agreement, the Act or any other applicable law, and each Investor shall continue to have the right to take for its own accounts or as a partner, shareholder, fiduciary or otherwise, or to recommend to others, any such particular opportunity. To the fullest extent permitted by applicable law, each Member (in its own name and in the name and on behalf of the Company) expressly waives any conflicts of interest or potential conflicts of interest and agrees that no Member or its Affiliates shall have any liability to any Member, any Affiliate thereof, or the Company with respect to such business or investment opportunities or any such related direct competition, conflicts of interest or potential conflicts of interest, and none of the same shall constitute a breach of this Agreement or of any duty expressed or implied by law to any Member or the Company. Each Member (in its own name and in the name and on behalf of the Company) acknowledges, affirms and agrees that (i) the execution and delivery of this Agreement by the Members is of material benefit to the Company and the Members, and that no Member would be willing to (x) execute and deliver this Agreement, and (y) hold the Units, without the benefit of this Section 2.11 and the agreement of the parties; and (ii) they have reviewed and understand the provisions of Sections 18-1101(b) and (c) of the Act.

Section 2.12 No Agency.

Nothing contained in this Agreement or in the Certificate of Formation shall be deemed to constitute any Member the partner of any other Member, respectively, to create any fiduciary relationship between them, nor, except as otherwise herein expressly provided, to constitute any Member the agent or legal representative of any other Member, respectively. No Member shall have any authority to act for or to assume any obligation or responsibility on behalf of the other Member in its individual capacity, except as otherwise expressly provided herein. Each Member shall indemnify, defend and hold harmless the other Member and its Affiliates, their directors, managers, officers, employees, agents and attorneys, and any Managers elected at the instance of the indemnified Member, from and against any and all losses, claims, damages and liabilities arising out of any act or assumption of liability by the indemnifying Member or any of their respective directors, managers, officers, employees, agents or attorneys or any Managers elected at the instance of it, done or undertaken, or apparently done or undertaken, on behalf of the other Member or the Company, except pursuant to authority expressly granted in the Certificate of Formation or in this Agreement or conferred in writing by the Board. Nothing in this Section 2.12 shall be deemed to lessen any power or authority, express or implied, of any director, manager, officer or committee of the Company.

 

20


Section 2.13 Priority of Agreements; Default Rules.

(a) This Agreement is the “limited liability company agreement” of the Company within the meaning of Section 18-101(7) of the Act. To the extent permitted by applicable Legal Requirements and the Act and as among the Members, the provisions of this Agreement shall apply to any matter related to the Company that is not covered by the Certificate of Formation. In the event of any inconsistency between the terms and conditions of the Certificate of Formation and the terms and conditions of this Agreement, the terms and conditions of this Agreement, to the extent permitted by the Act, shall apply by the means set out in the following sentence. The Members shall, subject to the Act, take such action as may be appropriate, including amending the Certificate of Formation, to remove such conflict, ambiguity or inconsistency and to permit the Company and its affairs to be carried on in accordance with this Agreement.

(b) Regardless of whether this Agreement specifically refers to a particular Default Rule, to the extent permitted under the Act, (i) if any provision of this Agreement conflicts with a Default Rule, the provision of this Agreement shall control and such Default Rule is hereby modified or negated accordingly and (ii) if it is necessary to construe a Default Rule as modified or negated in order to effectuate any provision of this Agreement, such Default Rule is hereby modified or negated accordingly.

Section 2.14 Liability Several.

The rights, duties, obligations and liabilities of the Members under the Certificate of Formation and this Agreement shall be several and not joint or collective. Each Member shall be responsible only for its obligations as set out in the Certificate of Formation and in this Agreement and shall be liable only for its share of costs and expenses as provided herein.

Section 2.15 Capacity of Members.

(a) General. As of the date hereof, Sponsor Member represents and warrants to Investor and Investor represents and warrants to Sponsor Member that, with respect to itself:

(i) it is duly organized and in good standing in its place of organization;

(ii) it has the capacity to enter into and perform this Agreement and all transactions contemplated herein and all limited liability company and other actions required to authorize it to enter into and perform this Agreement have been properly taken;

(iii) it is not subject to any governmental order, judgment, decree, debarment, sanction or laws that would preclude the execution or implementation of this Agreement;

(iv) this Agreement has been duly executed and delivered by it and is valid and binding upon it in accordance with its terms;

(v) it owns its Units free of any Encumbrances (other than those set forth in this Agreement);

 

21


(vi) no Person has any right or option to acquire from it or its Affiliates, directly or indirectly, any right, title or interest of any nature in or to its Units; and

(vii) it is a “United States person” within the meaning of Section 7701(a)(30) of the Code.

(b) Survival. The representations and warranties contained in Section 2.15(a) shall survive the execution hereof for a period of two years from the date hereof. The time permitted for bringing a claim may be affected by any applicable limitation periods under applicable Legal Requirement of the State of Delaware.

Section 2.16 U.S. Tax Provisions.

This Agreement shall incorporate the U.S. tax provisions of Schedule B, which shall constitute an integral part of this Agreement; including provisions requiring the Company to establish and maintain capital accounts for each Member and to allocate items of income, gain, deduction, loss and credit to such capital accounts. So long as the Company is treated as a partnership for federal income tax purposes, to ensure that Units are not traded on an established securities market within the meaning of Treasury Regulations Section 1.7704-1(b) or readily tradable on a secondary market or the substantial equivalent thereof within the meaning of Treasury Regulations Section 1.7704-1(c), (i) the Company shall not participate in the establishment of any such market or the inclusion of its Units thereon, and (ii) the Company shall not recognize any Transfer made on any such market by: (A) redeeming the Transferring Member (in the case of a redemption or repurchase by the Company); or (B) admitting the Transferee as a Member or otherwise recognizing any rights of the Transferee, such as a right of the Transferee to receive Company distributions (directly or indirectly) or to acquire an interest in the capital or profits of the Company; provided, however, that this Section 2.16 shall not apply if one or more of the secondary market safe harbors described in Treasury Regulations Section 1.7704-1 applies.

ARTICLE III.

MEMBERS

Section 3.01 Members.

The Members of the Company as of the date of this Agreement and their addresses shall be listed on Schedule A and said schedule shall be amended from time to time to reflect the withdrawal of Members and the admission of additional Members pursuant to this Agreement without requiring an amendment to this Agreement. The Members shall constitute a single class or group of members of the Company for all purposes of the Act, unless otherwise explicitly provided herein. The Board shall promptly notify the Members of any changes in Schedule A, which (to the extent in accordance with this Agreement) shall constitute the record list of the Members for all purposes of this Agreement and the Board shall provide a copy of Schedule A to any Member upon request. Members may designate a different address by a notice given to the Company and, upon delivery of such notice, the Board shall so amend Schedule A hereto to reflect such change and provide a copy of such amended Schedule A to each Member. Members holding (a) Preferred Units are individually referred to herein as a “Preferred Member” and collectively as the “Preferred Members” and (b) Members holding Common Units are individually referred

 

22


to herein as a “Common Member” and collectively as the “Common Members”; provided that to the extent that Members hold more than one class of Units, the term “Preferred Member” shall only refer to any Member holding Preferred Units with respect to its Preferred Units only and the term “Common Member” shall only refer to any Member holding Common Units with respect to its Common Units only.

Section 3.02 Units.

(a) General. The Members shall have no interest in the Company other than the interest conferred by this Agreement representing, with respect to any Member at any particular time, that Member’s membership interests (including its rights as a Member hereunder), which shall be represented by such Member’s Units. Every Member by virtue of having become a Member shall be held to have expressly assented and agreed to the terms hereof and to have become a party hereto. Ownership of a Unit shall not entitle a Member to any title in or to the whole or any part of the property of the Company or right to call for a partition or division of the same by court decree or operation of law or for an accounting, or for the right to own or use particular or individual assets of the Company or any of its subsidiaries. Except as expressly provided herein, each Member agrees and acknowledges that the business and affairs of the Company shall be managed exclusively by the Board.

(b) Initial Designation.

(i) The Company is initially authorized to have three (3) classes of Units, designated as Class A Common Units (“Class A Units”), Class B Common Units, which, for the avoidance of doubt, shall (subject to Section 6.02(a)) rank pari passu with the Class A Units as to distribution rights and distributions upon liquidation, winding-up and dissolution of the Company (“Class B Units” and, together with Class A Units, “Common Units”) and Preferred Units (“Preferred Units”). Except as expressly provided herein, including subject to Section 3.04 and Section 4.03, the Board has the exclusive authority to issue Units and to authorize additional Units for issuance. The Units issued to a Member may be represented by a certificate, at the request of such Member.

(ii) The Preferred Units, with respect to distribution rights and distributions upon liquidation, winding-up and dissolution of the Company, rank:

(A) senior to all Common Units, and to each other class of Units established after the date hereof by the Board, the terms of which do not expressly provide that it ranks senior to or pari passu with the Preferred Units as to distribution rights and distributions upon liquidation, winding-up and dissolution of the Company;

(B) ratably with any class of Units established by the Board and issued by the Company, the terms of which expressly provide that such class or series will rank pari passu with the Preferred Units as to distribution rights and distributions upon the liquidation, winding-up and dissolution of the Company; and

(C) junior to any class of Units established by the Board and issued by the Company, the terms of which expressly provide that it ranks senior to the Preferred Units as to distribution rights and distributions upon the liquidation, winding-up and dissolution of the Company.

 

23


(iii) The Common Units, with respect to distribution rights and distributions upon liquidation, winding-up and dissolution of the Company, rank:

(A) junior to all Preferred Units and any class of Units established by the Board and issued by the Company, the terms of which expressly provide that it ranks senior to the Common Units as to distribution rights and distributions upon the liquidation, winding-up and dissolution of the Company.

(B) ratably with any class of Units established by the Board and issued by the Company, the terms of which expressly provide that such class or series will rank pari passu with the Common Units as to distribution rights and distributions upon the liquidation, winding-up and dissolution of the Company.

(c) Initial Capital Contribution. Each Member has made or is deemed to have made an initial Capital Contribution, if any, allocated among Units on Schedule A (each, an “Initial Capital Contribution”). Schedule A shall also set forth the agreed upon initial capital account of each of Sponsor Member and Investor. No Member shall be required to make any additional Capital Contributions to the Company without the consent of such Member. Any non-cash contributions will be valued at their fair market value, as determined in good faith by the Board and in accordance with the definition of “Carrying Value” set forth in Schedule B.

(d) Certificates. The Company hereby irrevocably elects that all of the Units shall constitute securities within the meaning of Article 8 of the Uniform Commercial Code (including Section 8-102(a)(15) thereof) as in effect from time to time in the State of Delaware and each other applicable jurisdiction. Each certificate evidencing the Units shall bear the following legend: “THIS CERTIFICATE EVIDENCES A MEMBERSHIP INTEREST IN CALCASIEU PASS HOLDINGS, LLC AND SHALL BE A SECURITY GOVERNED BY ARTICLE 8 OF THE UNIFORM COMMERCIAL CODE AS IN EFFECT IN THE STATE OF DELAWARE AND, TO THE EXTENT PERMITTED BY APPLICABLE LAW, EACH OTHER APPLICABLE JURISDICTION.” All Units shall be represented by a certificate in the form of Schedule E attached hereto and, accordingly, each such certificate shall be deemed to be a “certificated security” within the meaning of the UCC. This Section 3.02(d) may not be amended or modified so long as any of the Preferred Units or Common Units are subject to a pledge or hypothecation without the prior written consent of such pledgee (or the transferee of such pledgee).

(e) No Reduction in Member’s Units. Except as otherwise provided in this Agreement or any award hereunder, the number of Units held by a Member shall not be reduced without such

Member’s consent.

Section 3.03 Conversion.

Upon the earlier of (a) the Commercial Operation Date and (b) both (i) a Liquidation Event (or event that the Preferred Members have elected to have treated as a Liquidation Event in accordance with Section 6.03) and (ii) an election by Investor to convert (clause (a) or (b), the “Conversion Date”), all Preferred Units shall automatically be converted, without the payment of

 

24


any additional consideration, into a number of fully paid and non-assessable Class B Common Units calculated in accordance with Schedule F. If any PIK Units are outstanding on the Conversion Date (which, for the avoidance of doubt, shall include any PIK Units issued on the Conversion Date pursuant to Section 6.01(a)), such PIK Units will be converted into an additional Percentage Interest in Class B Units calculated in accordance with Schedule F. If a closing of a Liquidation Event (or event that the Preferred Members have elected to have treated as a Liquidation Event in accordance with Section 6.03) occurs and Investor has elected to convert its Preferred Units, all outstanding Preferred Units shall be deemed to have been converted into shares of Class B Common Units immediately prior to such closing.

Section 3.04 Pre-Emptive Rights.

(a) Each Member (for the purpose of this Section 3.04, each a “Pre-Emptive Right Holder”) shall have the right to purchase such Pre-Emptive Right Holder’s Percentage Interest calculated assuming that a conversion pursuant to Section 3.03 has occurred as of such date (for the purpose of this Section 3.04, the “Pre-Emptive Allocation”) of any new Units that the Company may, from time to time, propose to sell and issue, including with respect to a Permitted Expansion pursuant to Section 4.06.

(b) In the event the Company proposes to undertake an issuance of new Units, it will give each Pre-Emptive Right Holder written notice of such issuance (which notice shall be delivered at least forty-five (45) days prior to such issuance), describing the new Units and the price and terms upon which the Company proposes to issue the same, and setting forth the number of shares or other number of new Units which such Member is entitled to purchase pursuant to such Member’s Pre-Emptive Allocation and the aggregate purchase price therefor. Each Pre-Emptive Right Holder will have thirty (30) days from the date of delivery of any such notice from the Company to agree to purchase new Units in an amount equal to such Member’s Pre-Emptive Allocation, for the price and upon the terms specified in the notice (provided, however, that the Pre-Emptive Right Holders shall be entitled to pay cash in lieu of any non-cash consideration) by giving written notice to the Company and stating therein the quantity of new Units to be purchased.

(c) In the event that after said thirty (30) day period (or, as applicable, such forty-five (45) day period) there exists any amount of new Units that have not been agreed to be purchased pursuant to the foregoing Section 3.04(b), the Company will (i) reoffer such Units to any Members that have fully subscribed for their Pre-Emptive Allocation, which Members will have fifteen (15) days to elect to acquire any or all such additional new Units (allocated based on their respective Pre-Emptive Allocations to the extent oversubscribed) and (ii) to the extent thereafter there remain any new Units that have not been agreed to be purchased, have one hundred eighty (180) days thereafter to sell such unsubscribed new Units, at a price no more favorable and upon such other terms not materially more favorable (taken as a whole) to the purchasers thereof than those specified in the Company’s notice. Any dilution of a Member’s Percentage Interest in connection with an issuance pursuant to this Section 3.04 shall be calculated in accordance with Schedule F. In the event the Company has not sold such new Units within said 180-day period, the Company will not thereafter issue or sell any new Units without first offering such new Units to each Pre-Emptive Right Holder in the manner provided above.

 

25


(d) Notwithstanding the requirements of Section 3.04(a), in the event that the Board reasonably determines in good faith that there are circumstances which would materially disadvantage (1) the Sponsor Member and the Investor in the same manner or (2) the Company, the Company may proceed with any issuance prior to having complied with the provisions of Section 3.04(a), provided, however, that the Company shall:

(i) provide each Pre-Emptive Right Holder with (i) prompt notice of (which in any event shall be no less than five (5) Business Days after) such issuance and (ii) the notice described in Section 3.04(a), in which the actual price per unit of new Units shall be set forth;

(ii) offer to issue to such Pre-Emptive Right Holder such number of new Units of the type issued in the issuance as may be requested by such Pre-Emptive Right Holder (not to exceed such Member’s Pre-Emptive Allocation) on the same economic terms and conditions with respect to such securities as the subscribers in the issuance (“New Subscribers”) received;

(iii) keep such offer open for a period of forty-five (45) days, during which period, each such Pre-Emptive Right Holder may accept such offer by sending a written acceptance to the Company and stating therein the quantity of new Units to be purchased, which in the event such acceptances in the aggregate exceed the quantity of new Units, shall be cut back proportionately so as not to exceed such Member’s Pre-Emptive Allocation of the new Units not subscribed for by other Pre-Emptive Right Holders; and

(iv) repurchase from the New Subscribers such number of new Units equal to the number of new Units acquired by the Pre-Emptive Right Holders under this Section 3.04(d) at the actual price per unit of the applicable new Units (with the net effect of such actions contemplated by the foregoing clauses (i) through (iii) and this clause (iv) being that the New Subscribers and Pre-Emptive Right Holders are in the same position as they would have been had Section 3.04(a) through Section 3.04(c) been followed).

Section 3.05 Action by Members.

No annual meeting of Members is required to be held. Any action required or permitted to be taken at any meeting of Members may be taken without a meeting if one or more written consents to such action shall be signed by the Members holding the amount of Units required to approve the action being taken. Such written consents shall be delivered to the Board at the principal office of the Company and to any Member that did not sign such written consent and, unless otherwise specified in any unanimous written Member consent, shall be effective on the date when the consent is so delivered and notice thereof is provided. The Board shall give prompt notice to all Members who did not consent to any action taken by written consent of Members without a meeting. No Person holding a Unit shall have any right to vote, approve, consent or participate in any decision by the Company or the Board in any way except as specifically set forth herein or as required by applicable law.

 

26


Section 3.06 Voting Rights.

Except as otherwise specifically provided herein or required by law, each outstanding Common Unit shall entitle the holder thereof to one vote on all matters for which the holders of Common Units are entitled to vote. Unless otherwise required by the Act or specified elsewhere in this Agreement, all approvals and consents to be taken or given by the Members shall require the affirmative vote or the written consent in accordance with Section 3.05 of the holders of a majority of the Percentage Interest entitled to vote thereon.

Section 3.07 Limitation of Liability of Members.

Except as otherwise provided in the Act, no Member of the Company shall be obligated personally for any debt, obligation or liability of the Company or of any other Member, whether arising in contract, tort or otherwise, solely by reason of being a Member of the Company. Except as otherwise provided in the Act, by law or expressly in this Agreement, no Member shall have any fiduciary or other duty to another Member with respect to the business and affairs of the Company, and no Member shall be liable to the Company or any other Member for acting in good faith reliance upon the provisions of this Agreement. No Member shall have any responsibility to restore any negative balance in its capital account or to contribute to or in respect of the liabilities or obligations of the Company or return distributions made by the Company except as required by the Act or other applicable law. The failure of the Company to observe any formalities relating to the exercise of its powers or the management of its business or affairs under this Agreement or the Act shall not be grounds for making its Members, Managers, or Officers responsible for any liability of the Company.

Section 3.08 Unit Transfers.

No Member shall, during the term of this Agreement, Transfer any of the Units now owned or hereafter acquired by it, except in compliance with the provisions this Agreement. The Company will not cause or permit the Transfer of its Units to be made on its register or other books unless the Transfer is permitted or required by the provisions hereof, and will not issue any Units or other equity interests whether by original issue, in connection with the sale of any outstanding equity interests of Company or in connection with any Transfer, except in accordance with the terms hereof. All Transfers of a Member’s Units shall be subject to the limitations on transferability set forth in Article VII. A notice reflecting the substance of such restrictions shall be entered in Schedule A.

Section 3.09 No Right to Withdraw.

Except as set forth in Article VII with respect to Transfers of Units, no Member shall have any right to resign or withdraw from the Company without the written consent of the other Members. Any Member resigning or withdrawing in contravention of this Section 3.09 shall indemnify, defend and hold harmless the Company and all other Members from and against any losses, expenses, judgments, fines, settlements or damages suffered or incurred by the Company or any such other Member arising out of or resulting from such resignation or withdrawal. No Member shall have any right to receive any distribution or the repayment of its Capital Contribution, except as provided in Article VI. For the avoidance of doubt, any Member

 

27


wrongfully resigning or withdrawing from the Company shall automatically forfeit all rights to future distributions from the Company, other than with respect to any distributions which have been declared, but unpaid as of any such resignation or withdrawal.

Section 3.10 Admission of New Members.

(a) The Company, with the consent of the Board and subject to the rights of Members and the other terms and provisions contained in this Agreement, is authorized to offer and sell, or cause to be offered and sold, additional Units and to exchange or cause to be exchanged additional Units for securities or other property both in accordance with the provisions hereof and to admit additional persons to the Company as Members who may participate in the profits, losses, distributions, allocations and Capital Contributions of the Company upon such terms as are established by the Board, which may include the authorization and issuance of additional Units or the designation and issuance of new classes of units or the establishment of classes or groups of one or more Members having different relative rights, powers and duties, including without limitation (but, for the avoidance of doubt, subject to the rights of Members and the other terms and provisions contained in this Agreement), rights and powers that are superior to those of existing Members, or the right to vote as a separate class or group on specified matters, by amendment of this Agreement under Section 11.04.

(b) New Members shall be admitted at the time when all conditions to their admission have been satisfied, as determined by the Board, and their identity and Units, as applicable, have been established by amendment of Schedule A.

Section 3.11 Exculpation and Indemnification.

(a) Exculpation. Notwithstanding any other provisions of this Agreement, whether express or implied, or obligation or duty at law or in equity, none of (i) the Members or any officers, directors, unitholders, partners, members, employees, representatives or agents of any of the foregoing, or (ii) the Managers or officers of Company (the Persons identified in clauses (i), and (ii), collectively, the “Covered Persons”) nor any former Covered Person shall be liable to Company or any other Person for any act or omission (in relation to Company, this Agreement, any related document or any transaction or investment contemplated hereby or thereby) taken or omitted in good faith by a Covered Person and in the reasonable belief that such act or omission is in or is not contrary to the best interests of Company and is within the scope of authority granted to such Covered Person by this Agreement; provided that a court of competent jurisdiction shall not have determined that such act or omission constitutes fraud, willful misconduct or bad faith.

(b) Indemnification. To the fullest extent permitted by law, Company shall indemnify and hold harmless each Covered Person and each former Covered Person from and against any and all losses, claims, demands, liabilities, expenses, judgments, fines, settlements and other amounts arising from any and all claims, demands, actions, suits or proceedings, civil, criminal, administrative or investigative (“Claims”), in which Covered Person may be involved, or threatened to be involved, as a party or otherwise, by reason of its management of the affairs of Company or which relates to or arises out of Company or its property, business or affairs. A Covered Person or former Covered Person shall not be entitled to indemnification under this Section 3.11 with respect to (i) any Claim with respect to which a court of competent jurisdiction

 

28


has determined that such Covered Person has engaged in fraud, willful misconduct or bad faith, or (ii) any Claim initiated by such Covered Person unless such Claim (or part thereof) (A) was brought to enforce such Covered Person’s rights to indemnification hereunder or (B) was authorized or consented to by the Board. Expenses incurred by a Covered Person in defending any Claim shall be paid by Company in advance of the final disposition of such Claim upon receipt by Company of an undertaking by or on behalf of such Covered Person to repay such amount if it shall be ultimately determined that such Covered Person is not entitled to be indemnified by Company as authorized by this Section 3.11.

(c) Effect of Modification. Any repeal or modification of this Section 3.11 shall not adversely affect any rights of such Covered Person pursuant to this Section 3.11, including the right to indemnification and to the advancement of expenses of a Covered Person existing at the time of such repeal or modification with respect to any acts or omissions occurring prior to such repeal or modification.

(d) Indemnitor of First Resort. Company hereby acknowledges that certain Covered Persons (the “Specified Covered Persons”) may have rights to indemnification and advancement of expenses provided by a Member or its Affiliates (directly or by insurance retained by such entity) (collectively, the “Member Indemnitors”). Company hereby agrees and acknowledges that (i) it is the indemnitor of first resort with respect to the Specified Covered Persons, (ii) it shall be required to advance the full amount of expenses incurred by the Specified Covered Persons, as required by the terms of this Agreement (or any other agreement between Company and the Specified Covered Persons), without regard to any rights the Specified Covered Persons may have against the Member Indemnitors and (iii) it irrevocably waives, relinquishes and releases the Member Indemnitors from any and all claims against the Member Indemnitors for contribution, subrogation or any other recovery of any kind in respect thereof. Company further agrees that no advancement or payment by the Member Indemnitors on behalf of Company with respect to any Claim for which the Specified Covered Persons have sought indemnification from Company shall affect the foregoing, and the Member Indemnitors shall have a right of contribution and be subrogated to the extent of such advancement or payment to all of the rights of recovery of the Specified Covered Persons against Company.

(e) Non-Exclusivity of Rights. The rights conferred on any Covered Person by this Section 3.11 shall not be exclusive of any other rights that such Covered Person may have or hereafter acquire under any statute, provision of this Agreement, agreement, vote of Members or Managers or otherwise.

ARTICLE IV.

GOVERNANCE MATTERS

Section 4.01 Board of Company.

(a) Board of Managers. The management and control of Company and its business and affairs, and the power to act for and to bind Company, shall be vested exclusively in the Board which shall consist of three Managers. The Board shall act as a “manager” pursuant to Section 18-402 of the Act. There shall be three members of the Board, one in respect of each Manager. Each Manager shall represent, and shall owe duties (fiduciary or otherwise) to, only the Member that

 

29


selected and appointed such Manager (the nature and extent of such duties being an internal corporate affair of such Member) and not to the Company or any of its subsidiaries, any other Member or Manager, or any Officer or employee of the Company.

(b) Selection of Managers.

(i) Prior to an exercise of the Step-In Right described in Section 4.01(b)(ii), two Managers will be selected and appointed by the Members holding Class A Units and one Manager will be selected and appointed by the Members holding Class B Units (or, prior to the Conversion Date, Preferred Units).

(ii) If any of the following shall occur:

(A) (1) an Event of Default (as such term is defined in the Project Financing Documents) has occurred, or (2) prior to the Commercial Operation Date, the Project Company has been prohibited for a period of at least 60 consecutive days from drawing loans under Project Financing Documents as a result of the failure to satisfy the conditions precedent to drawing thereunder (to the extent not waived by the Senior Lenders such that the Company is not so prohibited) (other than any such condition precedent that has not been satisfied due to the breach or default by the Preferred Member hereunder) and the Company is not diligently pursuing a remedial plan to remedy such prohibition to the reasonable satisfaction of the Members holding Class B Units or the Preferred Member, as applicable;

(B) a material breach by the Company or any of its subsidiaries of any of the Key Project Contracts that (with notice, the passage of time or otherwise) could, if uncured, result in termination of such Key Project Contract, or the termination of any Key Project Contract by the counterparty thereto in accordance with the terms of such Key Project Contract, in each case, in which the Company is not diligently pursuing a remedial plan to remedy such breach or restore or replace such Key Project Contract to the reasonable satisfaction of the Members holding Class B Units or Preferred Member, as applicable;

(C) any material breach of the Sponsor Member LLC Agreement (other than by the Redeemable Preferred Unit Holders) that is adverse to the Redeemable Preferred Unit Holders in a material respect and that is not cured within thirty (30) days after the Preferred Member (as defined in the Sponsor Member LLC Agreement) has provided notice of such breach;

(D) a significant casualty or condemnation event or loss of the U.S. Department of Energy export license related to the Project or other material Governmental Authorization, in each case, that (1) results in the cessation of commercial operations of the Project in the ordinary course of business for a period of at least 30 days and (2) which the Company is not diligently pursuing a remedial plan to the reasonable satisfaction of the Members holding Class B Units or the Preferred Member, as applicable;

 

30


(E) the Commercial Operation Date shall not have occurred by the date that is [***] days prior to the Date Certain (as such term is defined in the Project Financing Documents);

(F) Accrued Distributions shall have occurred for six consecutive calendar quarters commencing with the first full quarter following the Commercial Operation Date;

(G) the aggregate amount of Accrued Distributions outstanding on the Redeemable Preferred Units following the Commercial Operation Date is greater than [***] ([***]%) of the aggregate principal amount (including then outstanding Accrued Distributions) of the outstanding Redeemable Preferred Units as of the Commercial Operation Date; or

(H) (i) the Company has not operated the Project, or caused the Project to be operated, as a Reasonable and Prudent Operator and (ii) as a result thereof, the annual aggregate liquefaction capacity of the Project available for production of LNG (whether or not produced or loaded) has been less than [***]% of annual 10.0 MTPA aggregate nameplate liquefaction capacity of the Project for a three consecutive Calendar Year period following the Commercial Operation Date, except to the extent caused by Force Majeure, in each case, in which the Company is not diligently pursuing a remedial plan to increase its annual aggregate liquefaction capacity to the reasonable satisfaction of the Members holding Class B Units or the Preferred Member, as applicable;

then the Members holding Class B Units (or, prior to the Conversion Date, Preferred Units) will have the right, upon delivery of notice to Company and the other Members, to elect to appoint two of the Managers (the “Step-In Right”) to serve in such capacity until and for so long as the circumstances that triggered such election pursuant to this Section 4.01(b)(ii) are continuing. In such event, the Members holding Class A Units shall have the right to appoint one of the Managers and any Manager previously appointed by the Members holding Class A Units who is not so appointed pursuant to this sentence shall resign from such positions. In the event that at any time each of the circumstances that triggered the election of the members holding Class B Units (or, prior to the Conversion Date, Preferred Units) pursuant to this Section 4.01(b)(ii) are no longer continuing, including in the case of Section 4.01(b)(ii)(E), the occurrence of the Commercial Operation Date (the first such date, the “Cure Date”), then the Members holding Class A Units will have the right, upon delivery of notice to Company and the other Members, to elect to appoint two of the Managers to serve in such capacity starting thirty (30) days following the Cure Date. Upon such election, the Members holding Class B Units (or, prior to the Conversion Date, Preferred Units) shall have the right to appoint one of the Managers and any Manager previously appointed by the Members holding Class B Units (or, prior to the Conversion Date, Preferred Units) who is not so appointed pursuant to this sentence shall resign from such positions, in each case, starting thirty (30) days following the Cure Date. For the avoidance of doubt, (x) nothing in this Section 4.01(b)(ii) shall be construed or interpreted to require an increase in the total number of Managers of the Board and (y) in the event any of the circumstances described in this Section 4.01(b)(ii) shall occur again at any time,

 

31


the right of the Members holding Class B Units (or, prior to the Conversion Date, Preferred Units) to appoint a majority of the Managers pursuant to this Section 4.01(b)(ii) will apply anew.

(c) Current Managers. The initial Managers appointed pursuant to this Section 4.01 are set forth in Schedule C.

(d) Procedures. A Manager may be removed and another appointed in his or her place at the instance of the Member who has the right to appoint the Manager.

Section 4.02 Meetings of Board.

(a) Regular, Special and Rescheduled Meetings.

(i) The Board shall hold regular meetings at least quarterly. Meetings shall be held at places within the United States (which may be in or outside the State of Delaware) determined by the Company, or otherwise as may be agreed to by the Managers or permitted pursuant to Section 4.02(d). The Company shall give 30 days’ prior notice to the Managers of such regular meetings. Additionally, any Manager may call a special meeting upon 15 days’ prior notice to the Company and the other Managers. In case of Emergency, reasonable notice of a special meeting shall suffice.

(ii) There shall be a quorum if at least one Manager appointed by the holders of Class A Units and one Manager appointed by the holders of Class B Units (or, prior to the Conversion Date, Preferred Units) are present. If a quorum is not present within 30 minutes following the time appointed for the commencement of the Board meeting, any Manager present may adjourn the meeting, which then shall be automatically rescheduled for the same time of day and at the same place on the second Business Day or any other Business Day thereafter selected by the Managers present at the location where the meeting is to be held; provided, however, that if an Emergency exists or is imminent whereby adjourning and rescheduling the meeting would adversely affect the Company and its subsidiaries, taken as a whole, in any material respect, then a quorum shall be deemed to be present if at least two Managers are present. The Company shall make a good faith effort to give notice to the Managers of the rescheduled meeting but otherwise shall be under no obligation to give any Manager notice thereof. If notice thereof has been provided by the Company, a quorum shall be deemed to be present at such rescheduled meeting for all purposes under this Agreement if at least two Managers are present. Only those items included on the agenda for the original meeting as included in the original notice of meeting may be acted upon at such a rescheduled meeting, but any matters may be considered with the consent of all three Managers.

(b) Presence of Other Persons. A Manager appointed by each Member may, upon notice provided to the Company and the Board and at the expense of such Member or its Affiliates, invite a maximum of three (3) other employees of such Member who have a reasonable business purpose for being present and are bound by appropriate confidentiality obligations, to attend any meeting of the Board which such Manager attends; provided that the Manager(s) representing the other Member consents, which consent need not be in writing, may be given by acquiescence and may not be unreasonably withheld.

 

32


(c) Agendas; Minutes. Each notice of a meeting shall include an itemized agenda prepared by the Company in the case of a regular meeting or by the Manager calling the meeting in the case of a special meeting, but any matters may be considered with the consent of all Managers. An Officer of the Company shall prepare minutes of all meetings, including a rescheduled meeting, and shall distribute copies of such minutes to the Managers within 20 days after the meeting. The minutes, when approved by each Manager in attendance at the meeting, shall be the official record of the decisions made by the Board and shall be binding on the Company and the Members. The minutes of a meeting shall be deemed to have been approved by a Manager unless such Manager objects in writing within 20 days after being provided with such minutes. Approval of the minutes shall not be a condition to the effectiveness of actions properly taken by the Board.

(d) Meetings by Video or Telephonic Means. The Board may hold meetings via telephone or by video conference so long as all participants are able to hear and speak to each other and decisions are confirmed in writing by the Managers.

(e) Voting. A vote of the Managers present in respect of a proposal submitted for a vote of the Board at a meeting at which a quorum is present is referred to as a “Vote”. Approval of a resolution or other proposal brought before the Board shall require a greater than 50% affirmative Vote of the number of Managers present at a meeting at which a quorum is present.

(f) Actions by Written Consent. Any action required or permitted to be taken at any meeting of the Board may be taken without a meeting if all of the Managers consent thereto, and the writing or writings (including any waivers of notice) are filed with the minutes of proceedings of the Board.

Section 4.03 Enhanced Approval.

(a) Matters Requiring Class B Approval. The Company shall not take and shall cause its subsidiaries (and its and their respective officers and agents) not to take, and none of the Managers or the Board shall cause or permit Company or any of its subsidiaries (or any of their respective officers or agents) to take, any of the following actions unless the proposed action is first approved by a majority of the Board and at least one of the Managers appointed by the Members holding Class B Units (or, prior to the Conversion Date, Preferred Units):

(i) make any change in the form of, or jurisdiction of organization of the Company;

(ii) seek or voluntarily consummate any liquidation, bankruptcy or assignment to the Company’s or any subsidiary thereof’s creditors, or any similar transaction, or any dissolution, recapitalization or reorganization of the Company or its subsidiaries;

(iii) enter into any merger, consolidation or similar business combination with respect to the Company or any of its subsidiaries;

 

33


(iv) except for a disposition of TCP (or all or substantially all of the assets of TCP) pursuant to a bona fide arms’ length third party transaction permitted under the Project Financing Documents, enter into any sale, lease, exchange or other disposal of assets of the Company or any of its subsidiaries for consideration, in a single transaction or a series of related transactions, in excess of $50 million, except as expressly required under the Project Financing Documents;

(v) issue, sell or redeem any equity interest, or any option, warrant or other security convertible into or exercisable for any equity interests (w) prior to the Conversion Date, to or of any Person (x) prior to the Redemption Date, to or of any Person that is not a Member and a party to this Agreement as of the date hereof, (y) in the case of any issuance or sale, at less than fair market value (as reasonably determined by the Board in good faith), or (z) in the case of any issuance or sale, consisting of Class B Units or that are senior to the Class A Units or senior to or pari passu with the Class B Units; provided, that this clause (v) shall not restrict any adjustment to the Percentage Interests of the then-existing Members in connection with a Permitted Expansion (solely as provided in Schedule F with respect to Permitted Expansions);

(vi) consummate or participate in any IPO;

(vii) make any material change in the nature of the business conducted by the Company or any of its subsidiaries (for the avoidance of doubt, other than any Permitted Expansion);

(viii) commence or settle any litigation, arbitration or administrative proceeding, in each case, with an estimated amount in controversy in excess of $[***] million or that would impose material and adverse injunctive or equitable relief on the Company or any of its subsidiaries;

(ix) amend or modify the Certificate of Formation, this Agreement or the equivalent governing documents of any of the Company’s subsidiaries;

(x) make any distributions of cash or property in respect of its equity interests, other than distributions permitted under Article VI;

(xi) other than as reasonably necessary in order to fund a Permitted Expansion, remedy an Emergency (including to comply with the Project Financing Documents), approve any new Budget or amend any existing Budget, or undertake any expenditure (including an expenditure resulting from a Self-Executing Action under any Sponsor Contract) or capital project not reflected in the then existing Budget that would cause total aggregate expenditures of the Company and its subsidiaries to exceed one hundred fifteen percent (115%) of the total aggregate expenditures (x) over the prior year’s Budget with respect to a new Budget or (y) over the then current total aggregate expenditures with respect to an existing Budget, as applicable;

(xii) consummate any joint ventures, acquisitions or investments in third parties (other than subsidiaries of the Company) that have a value individually in excess of $[***] million or a value in aggregate in excess of $[***] million;

 

34


(xiii) make any election, file any amended return, change any tax accounting method (requiring approval by the IRS or other applicable Governmental Authority) or period, modify the method of allocations set forth in Schedule B, or take any other action with respect to taxes or otherwise, in each case, which is reasonably likely to result in an adverse change to the tax position of the Company or the tax liability of the Members or the Company, in each case; provided that any election (or change in election) with respect to the tax classification of any of the Company or any of its subsidiaries shall be deemed to result in such change for such purposes;

(xiv) enter into any material hedging transactions for speculative purposes;

(xv) other than entering into Self-Executing Actions, enter into any transaction with a Related Party or any new Sponsor Contract or amend an existing Sponsor Contract, in each case, if the terms and conditions thereof are not commercially reasonable (from the perspective of the Company and its subsidiaries) and are more favorable to a Related Party than could be obtained on an arm’s length basis (as certified in a written report or opinion from an independent valuation or engineering expert with appropriate qualifications in the case of any anticipated costs to the Company and its subsidiaries in excess of $[***] million in any Calendar Year);

(xvi) take any discretionary Self-Executing Action under any Sponsor Contract that is not commercially reasonable (from the perspective of the Company and its subsidiaries) and adversely affects the Company or any of its subsidiaries in a material manner;

(xvii) enter into any transaction, agreement, contract or amendment that would adversely affect in any material respect the rights (or the free exercise thereof) of the Members holding Class B Units (or, prior to the Conversion Date, Preferred Units), as applicable, under this Agreement or of the Redeemable Preferred Unit Holders under the Sponsor Member LLC Agreement, including any agreement or contract that would restrict Transfers that would otherwise be permitted or the exercise of any remedies or governance rights;

(xviii) except for consents to assignment, recognition agreements, pledges and similar amendments as may expressly be required by the Project Financing Documents to perfect the security or collateral interests or preserve the rights and remedies of the Senior Lenders, amend or terminate (other than terminating in accordance with its existing term in the ordinary course of business unrelated to any breach, default or failure to perform by the Company or any of its subsidiaries) any Key Project Contract, or enter into any new material agreement related to the Project; provided that it shall not be a violation of this clause (xviii) for the Company to, or to cause any of its subsidiaries to:

(1) amend (other than an amendment to reduce pricing or annual contract quantity or decrease tenor in any Foundation LNG SPA) any Key Project Contract so long as any such amendment could not reasonably be expected to have an adverse effect in any material respect on the Company and its subsidiaries, taken as a whole;

 

35


(2) enter into, amend or terminate any agreement (other than a Key Project Contract) so long as any of the foregoing could not reasonably be expected to have a material and adverse effect on any of the Company, its subsidiaries, the Investor or the Members holding Class B Units (or, prior to the Conversion Date, Preferred Units), as applicable, or the Redeemable Preferred Unit Holders;

(3) enter into one or more LNG sale and purchase agreements in replacement of a Foundation LNG SPA (each, a “Replacement SPA”) so long as (A) the aggregate annual committed minimum volume or “take or pay” contract quantity of LNG to be purchased from the Company or its subsidiaries pursuant to such Replacement SPA(s) is at least equal to the annual contract quantity of such Foundation LNG SPA, and any annual contract quantity required to be delivered by the Company or its subsidiaries under such Replacement SPA is reasonably anticipated in good faith by the Board to be met in the ordinary course of business without issue, (B) the Replacement SPA(s) is entered into with (x) a counterparty to a Foundation LNG SPA (or its Affiliate) or (y) a counterparty that is rated at least BBB- by Standard & Poor’s Ratings Services or Fitch, Inc. or at least Baa3 by Moody’s Investors Service, Inc. (or whose obligations are guaranteed by such an entity) and is a person to whom the Company or its subsidiaries is permitted to export LNG under its export authorizations and other applicable Governmental Authorizations and (C) the Board, in its good faith reasonable judgment, determines that the terms and conditions of such Replacement SPA are in the best interests of the Company at such time;

(4) enter into one or more LNG sale and purchase agreements in respect of (i) the 2.0 MTPA of Uncontracted Nameplate Capacity of the Project or (ii) any LNG to be produced and sold prior to the Commercial Operation Date; and/or

(5) enter into one or more change orders under the Key Project Contracts referenced in clauses (a), (b), (d) or (e) of the definition thereof that do not, individually or when taken together with all other change orders and then made or reasonably anticipated expenditures not originally included in such construction budget, exceed the contingency amount in the construction budget delivered on the date of the Project Financing Documents (as such amount is replenished with any deposits into the any contingent reserve account established under the Project Financing Documents);

(xix) Abandon the Project;

(xx) incur any additional indebtedness for borrowed money in excess of $[***] million, except for (A) a refinancing of the Project Financing (in an amount that does not materially increase the aggregate principle amount outstanding or available thereunder, other than negative carry or to provide for draws to pay fees, costs or expenses associated with such refinancing) so long as the terms of such refinancing are not materially less favorable (taken as a whole) to the Project Company than then-prevailing market terms in connection with any such refinancing and the proceeds thereof, if incurred prior to the Commercial Operation Date, are used solely to defease existing indebtedness and

 

36


otherwise to fund construction and operation costs of the Project; (B) indebtedness for borrowed money incurred prior to the Commercial Operation Date and used solely to fund construction and operation costs of the Project, or otherwise incurred following the Commercial Operation Date, in each case, to the extent such indebtedness and incurrence is permitted by the Project Financing Documents (as in effect on the date of the Closing Date); (C) a working capital facility; provided that the availability of such facility for expenses not related to natural gas purchases by the Project Company shall be limited to $[***] million, and any borrowings thereunder are used solely to fund ordinary course operational working capital needs of the Company and its subsidiaries; or (D) in connection with any Permitted Expansion, an amount of indebtedness for borrowed money that, on a pro forma basis after the incurrence thereof, allows the Company and/or its subsidiaries to satisfy the conditions specified in Section 4.06; provided that, in the case of this clause (xx)(A) or (D), such additional indebtedness is incurred only by, and only with recourse to, the Project Company or the equity interests therein; or

(xxi) agree, commit, or delegate authority to take any of the foregoing actions.

(b) Matters Requiring Class A Approval. In the event of an exercise of the Step-In Right in accordance with Section 4.01(b)(ii), then for so long as such Step-In Right is effective, the Company shall not take and shall cause its subsidiaries not to take, and none of the Managers or the Board shall cause or permit Company or any of its subsidiaries to take, any of the actions set forth in Section 4.03(a)(i) through (xx) unless the proposed action is (i) first approved by a majority of the Board and at least one of the Managers appointed by the Member holding Class A Units or (ii) necessary, in the reasonable opinion of the Investor or the Member holding Class B Units, as applicable, acting in the best interests of the Company and its Members, to remedy or eliminate the circumstances that triggered any election of the Investor or the members holding Class B Units, as applicable, pursuant to Section 4.01(b)(ii).

Section 4.04 Subsidiary Boards; Committees.

(a) To the extent any subsidiary of the Company is not a member-managed limited liability company, the Company shall take all necessary action to ensure that the board of directors or similar governing body of such subsidiary shall be comprised of designees of the Members holding Class A Units and the Members holding Class B Units (or, prior to the Conversion Date, Preferred Units) that, as nearly as practicable, are in proportion to the number of their respective designees on the Board and (subject to and without limiting, in each case, any applicable requisite consent of any Member(s), to the extent otherwise expressly required hereunder) require the vote, consent or decision (and presence for quorum) of each such designee to the same extent as would be required for comparable actions and meetings at the Board (including, for the avoidance of doubt, following any change in composition of the Board after the election of the members holding Class B Units (or, prior to the Conversion Date, Preferred Units) pursuant to Section 4.01(b)(ii)).

(b) The Board may also establish from time to time such other advisory committees as the Board determines to be necessary or desirable to facilitate the operations of the Company; provided that (a) no such committee may take any action that the Board is unable to take on its own accord and (b) each such committee shall include at least one Manager appointed by the Members holding Class A Units and one Manager appointed by the Members holding Class B

 

37


Units (or prior, to the Conversion Date, the Preferred Units). The Board will determine (i) the scope and authority of each such committee, (ii) the procedures for convening committee meetings and (iii) the duration of any such committee.

Section 4.05 Agreement to Take Corporate Actions.

(a) Subject to applicable Legal Requirements, the Members shall themselves do and pass, and/or cause Company at all times thereafter to do and pass, or cause to be done and passed in a timely manner without undue delay, all such acts, meetings, resolutions and corporate actions, and from time to time execute and deliver or cause to be executed and delivered such documents, instruments and agreements as may be required under applicable Legal Requirements or as may be necessary or advisable in the reasonable opinion of any Member, to give effect to and to be responsive to and consistent with the terms and provisions of this Agreement, and to resolutions Approved by Company so that the Members and Company will become subject to all of the obligations and liabilities expressed to be imposed upon them respectively hereunder and the intentions of the Members expressed hereunder can be implemented. The Members agree to attend duly called meetings and vote their Units and otherwise to act in every manner permitted under applicable Legal Requirements, to cause Company to act in the manner provided for herein and in the manner set forth in duly Approved resolutions of the Board and to give effect to the provisions of this Agreement and its purpose and intent, and to the extent necessary and permitted by Legal Requirements. The Members, so long as any of their nominees are Managers, agree to cause their nominees to attend duly called meetings and, to the extent that they are permitted by applicable Legal Requirements to do so, to cause their nominees to act and vote as Managers respectively so that the purpose and intent of this Agreement shall be carried out, and they shall remove any such nominee who shall consistently fail in this respect.

(b) Following the Commercial Operation Date, subject to applicable Legal Requirements and limitations contained in the Project Financing Documents, the Company shall cause the Company’s subsidiaries (including the Project Company and Pledgor) to distribute all of its Available Cash to the Company on a quarterly basis.

Section 4.06 Expansion.

None of the Sponsor Member or any of its Affiliates shall participate in any Facility Expansion other than through the Company or any of its subsidiaries, and (subject to the applicable terms of this Agreement) the Company shall be permitted at any time, on not less than thirty (30) days’ prior notice to each of the Members, to undertake a Facility Expansion so long as: (a) the Company has received an appropriate confirmatory report from the Independent Engineer that such Facility Expansion would not reasonably be expected to adversely affect the performance by TCP of its obligations to the Project Company or the performance by the Project Company of its obligations under the Foundation LNG SPAs; (b) all Governmental Authorizations necessary to undertake the Facility Expansion and simultaneously operate the Project have been obtained and are in full force and effect; (c) the financial model for the Project Company demonstrates, after giving effect to the indebtedness to be incurred by the Project Company in respect of such Facility Expansion, (i) a debt to equity ratio of not more than [***] and (ii) a debt service coverage ratio of not less than [***] in respect of each year following the completion of the Facility Expansion; and (d) the liquefaction (nameplate) capacity of the Facility Expansion does not exceed [***] MTPA

 

38


(when taken together with the liquefaction (nameplate) capacity of all other Facility Expansions) (a Facility Expansion satisfying each of the above criteria in clauses (a) through (e), a “Permitted Expansion”). Each Member shall have the right to participate in the equity financing of any Permitted Expansion in accordance with the provisions of Section 3.04.

Section 4.07 Contracts with Sponsor Member and its Affiliates.

(a) The Members hereby ratify, confirm and approve the Company or its subsidiary entering into, and performing its obligations under, the Sponsor Contracts set forth on Schedule H. The Members further acknowledge and agree that certain of the Sponsor Contracts provide for or contemplate, from time to time, entering into ancillary agreements, purchase orders, bills of sale, amendments, elections or other actions that are intended to be self-executing under such agreements in the ordinary course operation by the Company and its subsidiaries of their business (the “Self-Executing Actions”).

(b) The Members agree that if any Self-Executing Action taken pursuant to a Sponsor Contract as described in Section 4.07(a) is not commercially reasonable (from the perspective of the Company and its subsidiaries) and adversely affects the Company or any of its subsidiaries in a material manner, such action shall be subject to Section 4.03(a)(xvi).

(c) The Company shall provide to the Members holding Preferred Units or Class B Units, as applicable, notice of any action taken by the conflicts committee (comprised of one or more independent directors) of the board of directors of Sponsor that relates to the Company or its subsidiaries. Such notice shall also include such background information provided to such conflicts committee and the conclusion reached by such conflicts committee.

(d) Notwithstanding anything to the contrary, in the event of any material breach or default by the Sponsor Member or any of its Affiliates (other than the Company and its subsidiaries) under a Sponsor Contract that could reasonably be expected to cause the Project Company to materially breach a Foundation LNG SPA or otherwise have an adverse impact on the Project in any material respect and that is not cured within thirty (30) days after the Preferred Member or the Members holding Class B Units, as applicable, has provided written notice of such material breach to the Company, the Class B Manager shall have the sole power, authority and discretion to direct and cause the Company and any of its subsidiaries to take any actions with respect to the exercise of rights with respect to, or prosecution of, such material breach or default by Sponsor Member or any of its Affiliates under such Sponsor Contract, acting in the best interests of the Company at such time.

ARTICLE V.

MANAGEMENT OF OPERATIONS

Section 5.01 Officers.

(a) Designation of Officers. The business of the Company shall be managed under the direction of the Board (and the Board shall be deemed to be the manager of the Company as set forth in Section 4.01 hereof) who may exercise all the powers of the Company, except as provided by law or this Agreement. The Board shall have the discretion to determine the duties of one or more of the following officers of the Company and any other officers it deems appropriate: a Chief

 

39


Executive Officer, a President, a Chief Operating Officer, a Chief Financial Officer, one or more Vice-Presidents, a Secretary, a Treasurer, one or more Assistant Secretaries, one or more Assistant Treasurers and any other officers that the Board deems necessary or convenient for the operation of the Company (each individually an “Officer” and, collectively the “Officers”) and shall have the authority to delegate any or all of its duties as manager to certain of such Officers. The Officers, to the extent of their powers, authority and duties set forth in this Agreement or otherwise vested in them by the Board, are agents of the Company for the purposes of the Company’s business and the actions of the Officers taken in accordance with such powers shall bind the Company. As of the date of this Agreement, the Officers of the Company are set forth on Schedule D.

(b) Qualification; Removal. The Officers may, but are not required to, be Members and shall hold office until their death, resignation or removal by the Board. Any Officer may resign as such at any time. Such resignation shall be made in writing and shall take effect at the time specified therein, or if no time is specified, at the time of its receipt by the Board. The acceptance of a resignation shall not be necessary to make it effective, unless expressly so provided in the resignation. All employees, agents and Officers shall be subject to the supervision and direction of the Board and may be removed, with or without cause, from such office by the Board and the authority, duties or responsibilities of any employee, agent or Officer of the Company may be suspended by or altered by the Board from time to time.

Section 5.02 Budget.

(a) Proposed Budget. The Officers shall submit a proposed Budget to the Board for each Calendar Year not later than October 15th of the preceding Calendar Year. The initial Budget for the Calendar Year in which the Closing Date falls is set forth on Schedule G.

(b) Approval by the Board. Not later than December 15th of the year immediately preceding Calendar Year to which such Budget relates, the Board must either (i) approve the proposed Budget in accordance with Section 4.02 and Section 4.03, or (ii) reject the proposed Budget by specifying any rejected items and proposed revisions to such items. The Officers shall submit a revised Budget for approval not later than fifteen (15) days following its receipt of a rejection from the Board.

(c) Changes by the Board. Subject to Section 4.03, the Board may make such changes to any proposed Budget as it deems fit prior to Approval.

(d) Deadlock. If the Board for any reason fails to timely Approve a Budget in accordance with Section 5.02(b), then the Board, pursuant to a resolution or written consent, (i) shall approve the proposed Budget with respect to all items not rejected by the Board pursuant to Section 5.02(b), (ii) to the extent that any remaining rejected items were provided for in the previous Budget Approved by the Board, each such rejected item shall be deemed approved in an amount equal to one hundred five percent (105%) of the last previously Approved amount (and all items approved or deemed approved in clauses (i) and (ii), together shall constitute the Approved Budget for purposes of the period covered by the proposed Budget to which they relate) and (iii) to the extent that any remaining rejected items were not provided for in the previous Approved Budget, such items shall not be deemed approved unless and until the Approved Budget is modified in accordance with Section 5.02(b).

 

40


(e) Activities During Delay. If the Board for any reason fails to timely Approve a Budget, the Company shall, subject to the contrary direction of the Board and to the availability of necessary funds, be authorized to continue, or to cause Company to continue, operations sufficient to maintain the assets of the Company or its subsidiaries and comply with applicable Legal Requirements and/or the requirements of the Project Financing Documents.

Section 5.03 Information Rights.

(a) General Information Rights. The Company will furnish to each Member the following information:

(i) As soon as available, but no later than one-hundred twenty (120) days following completion of each fiscal year, the audited consolidated balance sheet of the Company and its subsidiaries as at the end of each such fiscal year and the audited consolidated statements of income, cash flows and changes in stockholders’ equity for such year of the Company and the subsidiaries, setting forth, in each case, in comparative form the figures for the next preceding fiscal year, accompanied by the report of independent certified public accountants of recognized national standing, to the effect that, except as set forth therein, such consolidated financial statements have been prepared in accordance with United States generally accepted accounting principles (“GAAP”) applied on a basis consistent with prior years and fairly present in all material respects the financial condition of the Company and the subsidiaries as of the dates thereof and the results of their operations and changes in their cash flows and stockholders’ equity for the periods covered thereby.

(ii) As soon as available, but no later than sixty (60) days following completion of each fiscal quarter (other than the fourth fiscal quarter), the consolidated balance sheet of the Company and the subsidiaries as at the end of such quarter and the consolidated statements of income, cash flows and changes in stockholders’ equity for such quarter and the portion of the fiscal year then ended of the Company and the subsidiaries, setting forth, in each case, the figures for the corresponding periods of the previous fiscal year in comparative form, all in reasonable detail and all prepared in accordance with GAAP consistently applied (subject to normal year-end adjustments and the absence of footnotes).

(b) Tax Information Rights. Within 120 days after the end of each fiscal year, the Company shall cause to be delivered to each Member (so long as such Member owned any Units during such prior fiscal year) all information necessary for the preparation of such Member’s income tax returns (whether federal, state or foreign).

(c) Investor Information Rights. From and after the Closing Date, the Company shall provide the Members with customary reports and information, including any reports or information required to be provided to the Senior Lenders under the Project Financing Documents, and including:

(i) all construction plans, construction budgets and construction progress and other reports delivered to the Senior Lenders under the Project Financing Documents;

(ii) copies of all reports received from the Independent Engineer;

 

41


(iii) annual operating plans and annual operating budgets for the Company and its subsidiaries, inclusive of management commentary;

(iv) monthly operational reports, including a comparison of performance to the annual operating budget, inclusive of management commentary;

(v) annual consolidated plans and financial forecasts of the Company;

(vi) copies of all reports submitted to the Company or its subsidiaries by auditors;

(vii) without duplication of the foregoing, copies of all periodic reports or certifications, and notices of material claims, default, termination or force majeure, to or from the Senior Lenders, Governmental Authorities or any party to a Key Project Contract (or any replacement thereof);

(viii) reasonable and customary inspection and visitation rights, including reasonable and customary access to members of senior management and any individual providing services to the Company or its subsidiaries that is employed by any Member and/or its Affiliates; and

(ix) other notices, information and data with respect to the Company and its subsidiaries or the Project as may be reasonably requested by any Member (including any information and data as may be required in order for such Member, its parent entity or their Affiliates to comply with reporting requirements under securities laws, any national securities exchange or automated quotation system or, to the extent reasonably required, agreements with limited partners or other investors).

ARTICLE VI.

DISTRIBUTIONS

Section 6.01 Distributions on Preferred Units.

(a) From and after the date hereof, except as provided in Section 6.01(c), each outstanding Preferred Unit shall receive distributions in-kind in the form of additional Preferred Units (“PIK Units”) on the Face Value at the Distribution Rate (each such distribution, a “PIK Distribution”) on the last day of each quarter. PIK Distributions shall accrue and be cumulative and shall be computed on the basis of a 360-day year comprised of four quarters of 90 days each. Such distributions shall be payable, whether or not declared by the Board, in accordance with this Section 6.01 to the Preferred Members as they appear on Schedule A. Any such PIK Distributions shall (without duplication) increase the aggregate Face Value of the Preferred Units.

(b) On the Conversion Date, any accrued but unpaid distributions on the Preferred Units shall be paid in the form of PIK Units to the Preferred Members as they appear on the Schedule A at the close of business on the Conversion Date for the pro rata portion of such quarter.

(c) Following the date that the Project has actually produced and loaded for sale to un-Affiliated third party commercial customers an amount of LNG in any single consecutive [***]

 

42


day period equal to at least [***] MMBtu, the Company, upon declaration by the Board, shall have the right, at its option, to elect to cause all or any portion of any PIK Distributions to be issued on any Quarterly Distribution Date occurring after such date to be instead paid for in cash (and, for the avoidance of doubt, such cash payment shall be in lieu of the increase in Face Value that would otherwise have occurred at the end of each quarter).

Section 6.02 Distributions on Common Units.

(a) For each full quarter ending on or prior to the Conversion Date, distributions on Class A Units shall be paid from Net LNG Sales Proceeds on each Quarterly Distribution Date following such declaration by the Board to the Members holding Class A Units as they appear on the Schedule A at the close of business on the relevant record date for such distribution.

(b) For any distributions of Available Cash following the Conversion Date, distributions on Common Units shall be paid from Available Cash on a quarterly basis on each Quarterly Distribution Date following such declaration by the Board to the Members holding Common Units as they appear on the Schedule A at the close of business on the relevant record date for such distribution. Notwithstanding anything to the contrary, (i) any distributions on Class A Units pursuant to this Section 6.02(b) concurrently with or following a distribution of a Special Class B Distribution Amount shall be reduced (without duplication) by an amount in the aggregate equal to such Special Class B Distribution Amount, if any (it being understood and agreed, for the avoidance of doubt, after such aggregate reduction has occurred one time, such reduction shall no longer apply in respect of such Special Class B Distribution Amount) and (ii) any distributions on Class B Units pursuant to this Section 6.02(b) concurrently with or following a distribution of a Special Class A Distribution Amount shall be reduced (without duplication) by an amount in the aggregate equal to such Special Class A Distribution Amount, if any (it being understood and agreed, for the avoidance of doubt, after such aggregate reduction has occurred one time, such reduction shall no longer apply in respect of such Special Class A Distribution Amount).

Section 6.03 Distributions Upon Liquidation.

(a) Upon any (i) liquidation, dissolution or winding up of or (ii) bankruptcy, insolvency or other similar event in respect of the Company and its subsidiaries, whether voluntary or involuntary (a “Liquidation Event”), each Preferred Member shall be entitled to be paid in cash, before any amount shall be paid or distributed to the Common Members, an amount per Preferred Unit equal to the Liquidation Price (such sum, the “Preferred Preference Amount”). If the amounts available for distribution by the Company to Preferred Members upon a Liquidation Event are not sufficient to pay the aggregate Preferred Preference Amount due to such Preferred Members, such Preferred Members shall share ratably in any distribution in connection with such Liquidation Event in proportion to the full respective preferential amounts to which they are entitled. After the prior payment in full of the Preferred Preference Amount in connection with a Liquidation Event, the remaining assets and funds of the Company available for distribution to its members, if any, shall be distributed among the Common Members in accordance with their Percentage Interest.

(b) The Preferred Members may elect to have treated as a Liquidation Event: (i) any merger, amalgamation or consolidation of the Company, Sponsor Member or Sponsor into or with

 

43


another corporation (except one in which the holders of shares of the Company, Sponsor Member or Sponsor, as applicable, immediately prior to such merger, amalgamation or consolidation continue to hold at least a majority of the voting power of the shares of the surviving corporation), (ii) any sale, Transfer or license of all or substantially all of the assets of the Company, Sponsor Member or Sponsor, (iii) any sale or Transfer of 50% or more of the voting rights of the Company, Sponsor Member or Sponsor to a person or group as such terms are used in section 13(d) and 14(d) of the Securities Exchange Act of 1934 (each such event, described in clauses (i) through (iii) a “Change in Control Event”), or (iv) an IPO. If such election is made, the Company shall be required to redeem the Preferred Units for an amount per Preferred Unit equal to the Liquidation Price, unless the Preferred Members agree otherwise in writing, and all consideration payable to the Members of the Company in connection with any such merger, amalgamation or consolidation or IPO, or all consideration payable to the Company, Sponsor Member or Sponsor and distributable to Members, together with all other available assets of the Company (net of obligations owed by the Company that are senior to the Preferred Units), in connection with any such asset sale, Transfer or license or IPO, shall be, as applicable, paid by the purchaser to the holders of, or distributed by the Company in redemption (out of funds legally available therefor) of, the Preferred Units as if such transaction were a Liquidation Event. In furtherance of the foregoing, the Company, Sponsor Member and Sponsor shall take such actions as are necessary to give effect to the provisions of this Section 6.03(b), including without limitation, (i) in the case of a merger, amalgamation or consolidation of the Company, causing the definitive agreement relating to such merger, amalgamation or consolidation to provide for a rate at which the Preferred Units are converted into or exchanged for cash, new securities or other property which gives effect to the provisions of this Section 6.03(b), (ii) in the case of a merger, amalgamation or consolidation of Sponsor Member or Sponsor, redeeming the Preferred Units for a price per Preferred Unit which gives effect to the provisions of this Section 6.03(b), (iii) in the case of an asset sale, Transfer or license of the Company, Sponsor Member or Sponsor, redeeming the Preferred Units for a price per Preferred Unit which gives effect to the provisions of this Section 6.03(b), or (iv) in the case of an IPO, redeeming the Preferred Units for a price per Preferred Unit which gives effect to the provisions of this Section 6.03(b). The Company and Sponsor Member shall promptly provide to the Preferred Members such information concerning the terms of such merger, amalgamation consolidation or asset sale or IPO, and the value of the assets of the Company or Sponsor Member as may reasonably be requested by the Preferred Members. The amount deemed distributed to the Preferred Members upon any such transaction shall be the cash or the value of the property, rights or securities distributed to such Preferred Members by the Company or the acquiring person, firm or other entity, as applicable. Any election by the Preferred Members of the then outstanding Preferred Units pursuant to this Section 6.03(b) shall be made by written notice to the Company at least five (5) days prior to the closing of the relevant transaction.

Section 6.04 Special Distributions.

(a) Commencing on the Commercial Operation Date and continuing until the twentieth (20th) anniversary of the Commercial Operation Date, if and for so long as in respect of any Calendar Year during such period there is any Uncontracted Nameplate Capacity, then notwithstanding anything herein to the contrary, on the Quarterly Distribution Date falling on the last day of the first quarter of each Calendar Year, so long as the customer under any two or more Foundation LNG SPAs has directly or indirectly purchased from the Company or its subsidiaries at least [***] of the contract quantity for such Calendar Year under each such Foundation LNG SPA:

 

44


(i) the Company shall distribute to the holders of the Class B Units an additional special distribution in an amount equal to the Special Class B Distribution Amount (if any); and

(ii) the Company shall distribute to the holders of the Class A Units an additional special distribution in an amount equal to the Special Class A Distribution Amount (if any).

ARTICLE VII.

TRANSFERS; PREFERENTIAL PURCHASE RIGHTS; EXEMPT TRANSFERS

Section 7.01 Restrictions on Transfer.

A Member shall have the right to Transfer its Units to any third party solely as provided in, and subject to, this Article VII and may not otherwise Transfer such Units. Except as set forth in Section 7.02, no Member may transfer any Units. Any Transfer not expressly permitted herein shall be void and of no effect.

Section 7.02 Permitted Transfers.

Notwithstanding anything to the contrary in Section 7.01, but subject to Section 7.05:

(a) a Member’s Units may be pledged to secure bona fide third party indebtedness and foreclosures (but excluding any subsequent Transfer) of such pledge may be made, and Permitted Upstream Transfers may be made;

(b) a Member may Transfer its Units to an Affiliate that is a direct or indirect wholly-owned subsidiary of such Member and that is not a Prohibited Person, provided that, in each case, such Affiliate shall assume the obligations of the Member and become a party to this Agreement in accordance with Section 7.05; and

(c) following expiration of the Lock-Up Period applicable to such Member, a Member may Transfer all or a portion of such Member’s Common Units to any Person who is not a Prohibited Person, as permitted by Section 7.03.

Section 7.03 Right of First Offer.

(a) Subject to Section 7.03(d), the provisions of this Section 7.03 and, as applicable, Section 7.04 shall apply to all Transfers of Common Units other than any Permitted Upstream Transfer.

(b) Subject to Section 7.03(d), if any Common Member desires to Transfer all or any of its Common Units, then such Common Member (the “Transferring Member”) shall first, before offering to Transfer Common Units to any other Person, give prior written notice to the Members who are not Transferring Members (collectively, the “Non-Transferring Members”)

 

45


of such intent and specify the Common Units which such Transferring Member is proposing to sell (the “ROFO Notice”). Within thirty (30) days from the date of receipt of the ROFO Notice, the Non-Transferring Members may either decline in writing to offer to buy such Common Units, or may propose in writing a price at, and terms and conditions on, which any such Non-Transferring Member offers to buy all (but not less than all) of such Common Units (each, a “Non-Transferring Member Offer” and collectively, the “Non-Transferring Member Offers”). The Transferring Member shall have sixty (60) days after receipt of the Non-Transferring Member Offers to either accept in writing a Non-Transferring Member Offer or to decline in writing any Non-Transferring Member Offer. If the Transferring Member accepts any Non-Transferring Member Offer, the Non-Transferring Member and Transferring Member shall consummate the closing of the sale and purchase of the subject Common Units pursuant to such Non-Transferring Member Offer as promptly as practicable and in no event later than the later of sixty (60) days following such acceptance and receipt of all requisite governmental or other third party consents (or at such other time as they may mutually agree). If all of the Non-Transferring Members decline to make a Non-Transferring Member Offer or if the Transferring Member declines all Non-Transferring Member Offers, the Transferring Member may thereafter, for a period of twelve (12) months after the date of the Non-Transferring Member Offer(s), sell or enter into an agreement to sell (pursuant to which such sale is ultimately consummated) any of the Common Units covered by the ROFO Notice to a Person that is neither an Affiliate nor a Prohibited Person at a price, and upon other terms and conditions in the aggregate (other than with respect to customary representations, warranties, interim covenants and indemnities for breaches thereof that third parties unaffiliated with the Company would reasonably anticipate in accordance with market practice, but which an existing Affiliated investor in the Company would not, and excluding any delay in closing due to governmental or other third party consents required to be obtained), no more favorable to the Transferee than the price, terms and conditions specified in the Non-Transferring Member Offer(s). To the extent Common Units are to be Transferred to a Non-Transferring Member pursuant to this Section 7.03(b), each Transferring Member shall cause such Common Units to be Transferred free and clear of all liens, claims, encumbrances and other restrictions (other than as set forth in this Agreement) and shall be deemed to have represented that such Transferring Member has full right, title and interest in and to such Common Units and has all necessary power and authority and has taken all necessary actions to sell such Common Units. The closing of any Transfer pursuant to this Section 7.03(b) shall occur in accordance with the terms and provisions of the offer and this Agreement.

(c) Any proposed Transfer by a Transferring Member not consummated within the time periods set forth in this Section 7.03 (other than due to a breach by the Non-Transferring Member of any obligation to consummate the purchase of subject Units pursuant to an accepted Non-Transferring Member Offer as required by Section 7.03(b)) shall again be subject to this Section 7.03 and shall require compliance by such Transferring Member with the procedures described in this Section 7.03. The exercise or non-exercise of the rights of any Member under this Section 7.03 with respect to any proposed Transfer shall not adversely affect its rights with respect to subsequent Transfers by a Transferring Member under this Section 7.03.

(d) The provisions of this Section 7.03 and Section 7.04 shall not apply to Transfers permitted by Section 7.02(a) or Section 7.02(b) or any foreclosure (but excluding any subsequent Transfer) of the pledge permitted by Section 7.02(a).

 

46


Section 7.04 Tag-Along Rights.

(a) If, pursuant to Section 7.03, none of the Non-Transferring Members make a Non-Transferring Member Offer or the Transferring Member declines all Non-Transferring Member Offers and, in either case, the Transferring Member is proposing to Transfer Common Units representing at least 30.0% of the then outstanding Common Units to a Person that is neither an Affiliate nor a Prohibited Person (any such party, a “Tag-Along Transferee”) in a transaction or series of related transactions (including by way of purchase agreement, merger or other business combination transaction or otherwise) (a “Tag-Along Sale”), then the Transferring Member shall deliver to each Non-Transferring Member (each such Non-Transferring Member, a “Tag-Along Member”) written notice of such proposed Transfer, which shall include all material terms thereof (including the anticipated time and place designated for the closing of such Transfer, the identity of the Tag-Along Transferee, the aggregate proposed purchase price therefor and the implied aggregate valuation for all of the Company’s outstanding equity interests (such implied value, the “Tag Price”)), and, if available, a copy of any form of agreement proposed to be executed in connection therewith (the “Tag-Along Notice”) prior to effecting such Transfer. Each of the Tag-Along Members shall then have the irrevocable right (a “Tag-Along Right”), exercisable by delivery of an irrevocable notice to the Transferring Member at any time within fifteen (15) Business Days after receipt of the Tag-Along Notice, to participate in the Tag-Along Sale. Subject to Section 7.04(c), each Tag-Along Member will Transfer its Common Units on substantially the same terms (including price per Common Unit) and conditions applicable to the Transferring Member; provided, that such terms and conditions are customary for such a transaction and the proportion of the then outstanding Common Units represented by such Common Units.

(b) If any Tag-Along Member has exercised its Tag-Along Right and the Tag-Along Transferee is unwilling to purchase all of the Common Units proposed to be Transferred by the Transferring Member and each exercising Tag-Along Member, then the Transferring Member and the exercising Tag-Along Members shall reduce, on a pro rata basis (based on the aggregate potential proceeds receivable in respect of the Common Units that were to be included in the Tag-Along Sale at the Tag Price), the respective amounts of such Common Units that the Transferring Member and each exercising Tag-Along Members would have sold so as to permit the Transferring Member and the exercising Tag-Along Members to sell the number of Common Units, in each case, determined in accordance with such pro rata basis, at the aggregate price that the proposed Tag-Along Transferee is willing to pay for such Common Units.

(c) To the extent that the Transferring Member and the Tag-Along Members Transferring Common Units in a transaction under this Section 7.04 are to provide any indemnification or otherwise assume any other post-closing liabilities, they shall do so severally and not jointly (and on a pro rata basis in accordance with the consideration received from the Tag-Along Transferee by each such Member in connection with the Tag-Along Sale; provided, that each of the Transferring Member and each Tag-Along Member shall be solely liable with respect to any representations and warranties relating to such Member’s good standing, due authorization, due execution, enforceability, lack of conflicts, title to the Common Units and investment qualifications), and each Member’s respective potential liability thereunder shall not exceed the proceeds received by such Member from the Tag-Along Transferee, except with respect to claims related to fraud or willful breach by such Member. In connection with a Tag-Along Sale, each Tag-Along Member will also (i) waive all dissenter’s rights and other similar rights, (ii) take all

 

47


actions reasonably required or desirable or requested by the Transferring Member to consummate such Tag-Along Sale and (iii) comply with the terms of the documentation relating to the Tag-Along Sale.

Section 7.05 Transfer Procedures.

(a) Except (i) pursuant to Section 7.03 and, if applicable, in compliance with Section 7.04 or (ii) pursuant to Transfers permitted by Section 7.02(a) or Section 7.02(b) or any foreclosure (but excluding any subsequent Transfer) of the pledge permitted by Section 7.02(a), no Member shall directly Transfer less than all of its Common Units or directly Transfer its Common Units to a Transferee that is not just one (1) Person (or Affiliated group of Persons) without the consent of the other Member, which may be withheld or conditioned at such Member’s sole discretion. Notwithstanding anything to the contrary, no direct Transfer of Units held by the Sponsor Member shall be made or effective (and any purported such Transfer shall be null and void) prior to the Redemption Date.

(b) No Transfer may be made unless the Transferee (if a direct Transferee) (A) agrees in writing to be bound by the provisions of this Agreement as though it were a Member hereunder, and (B) unless waived by the Board (acting through the Class B Manager pursuant to Section 4.07(a), if applicable), causes to be delivered to the Company, at such Transferee’s sole cost and expense, a favorable opinion from legal counsel reasonably acceptable to the Board (or a designee of the Board to whom such authority has been delegated), to the effect that such Transfer does not violate or result in registration being required under any applicable law. In addition, such Transferee shall execute and deliver such other instruments and documents, in form and substance reasonably satisfactory to the Board (including any instrument necessary to cause the Transferee to become a Member), as are reasonably requested by the Company in connection with such Transfer, and all other Members agree to execute and deliver such amendments hereto as are reasonably necessary to cause such Transferee to become a Member if requested by the Board.

(c) Any Transfer that would cause a Person other than a wholly-owned subsidiary of Sponsor to obtain Control of the Company shall be void ab initio unless such Person shall not cause a “Change of Control” (as defined in the Project Financing Documents).

(d) Any Transfer that would cause the Company to be treated as a “publicly traded partnership” within the meaning of Section 7704 of the Code and the Treasury Regulations thereunder shall be void ab initio.

(e) Notwithstanding anything to the contrary herein, no Member may Transfer all or any portion of its Units to any Person that is not a “United States person” within the meaning of Section 7701(a)(30) of the Code.

(f) Any Transfer that would cause (1) an Event of Default (as such term is defined in the Project Financing Documents), or other breach or default which (with notice, passage of time or otherwise) would give rise to the right of the Senior Lenders to exercise remedies under the Project Financing Documents, (2) a material breach by the Company or any of its subsidiaries, or termination, of any of the Key Project Contracts or (3) a material breach by the Sponsor Member or any of its Affiliates of the Sponsor Member LLC Agreement shall be void ab initio.

 

48


(g) Any Transfer that would breach, violate or result in material non-compliance with any Governmental Authorization issued by FERC or the U.S. Department of Energy shall be void ab initio.

(h) The Members shall take, or shall cause Company to take, any actions as may be required to approve any Transfers of Common Units that are authorized in accordance with the provisions of this Article VII.

(i) The Company will reasonably (and use commercially reasonable efforts to cause its representatives to) cooperate in connection with any contemplated Transfer of Common Units (including, without limitation, participation in diligence and marketing efforts) at the sole expense of the Transferring Member.

(j) The terms and conditions of any confidentiality agreement relating to a proposed Transfer by a Member are subject to the Company’s prior approval (not to be unreasonably withheld, conditioned or delayed) to the extent such confidentiality agreement does not protect the Confidential Information from further disclosure by such potential Transferee to the same extent as the Parties are obligated under Article IX; and each such Member agrees that it shall enforce and cause any such potential Transferee to abide by Article IX as if such proposed were directly bound thereby to the same extent as such member).

Section 7.06 Exit Cooperation.

(a) Following the expiration of the Lock-Up Period, if so requested by the Investor, the Company and each other Member shall use commercially reasonable efforts to assist with and facilitate the marketing of the Transfer of any or all of the Units owned by the Investor or its Affiliates and any related Transfer transaction, including (in the case of the Company) by retaining an investment banker and legal counsel selected by the Investor (and reasonably acceptable to the Company) to market and implement the transaction to prospective investors that are permitted to acquire such Units in accordance with the terms hereof, making available reasonable due diligence information related to the Company and its subsidiaries and making its officers and personnel available to reasonably participate in connection with such efforts, provided, that neither the Company nor any Member nor any of their respective Affiliates shall be required to, or to cause any other Person to, waive any rights, make any concessions, incur any material liability or obligation, or amend or modify the terms of any contract or agreement in connection with the provision of the marketing assistance as contemplated hereby, and provided further, that the Company shall be entitled to establish reasonable due diligence processes and procedures so as to minimize the disruption on the ordinary operations of the Company and its subsidiaries. All fees, costs and expenses incurred by the Company, any non-participating Member or any of their respective Affiliates in connection with any transaction (whether or not consummated) arising from the exercise of the marketing rights described in this Section 7.06 (including the fees, costs and expenses of any investment banker or legal counsel engaged by the Company, any such non-participating Member or any of their respective Affiliates, but not including any internal costs or overhead incurred by the Company or any non-participating Member or any of their respective Affiliates in furtherance of this Section 7.06) shall be borne and paid by the Investor or its Affiliates.

 

49


(b) For the avoidance of doubt, Section 7.06(a) shall not limit the applicability of the other clauses of this Article VII.

(c) Notwithstanding anything herein to the contrary, if as of the date that is the ten (10) year anniversary of the Closing Date the Investor or any of its Affiliates hold any Units, the restrictions included in this Article VII (other than Section 7.05(b), (d), (f)(1), (f)(2) or (g)) shall no longer apply to the Investor or any such Affiliate, but, for the avoidance of doubt the foregoing restrictions shall still apply to each other Member; provided, that this Section 7.06(c) shall not permit Investor or any such Affiliate to Transfer any Units to any Prohibited Person.

ARTICLE VIII.

GOVERNING LAW; DISPUTES

Section 8.01 Governing Law; Consent to Jurisdiction.

This Agreement shall be construed and enforced in accordance with and governed by the laws of the State of Delaware, without regard to choice of laws or conflict of laws principles that would require or permit the application of the laws of any other jurisdiction. Each of the Parties hereby irrevocably attorns and submits to the exclusive jurisdiction of the Court of Chancery of the State of Delaware (or in the event that such court does not have jurisdiction, to the exclusive jurisdiction of the U.S. District Court for the District of Delaware) respecting all matters relating to this Agreement and the rights and obligations of the Parties hereunder. Each of the Parties hereby agrees that service of any legal proceedings relating to this Agreement may be made by physical delivery thereof to its address provided in, or in accordance with, Section 11.01.

Section 8.02 Dispute Resolution.

(a) Except as otherwise provided herein, in the event of any dispute, claim or difference arising between the Parties in respect of the subject matter, the interpretation or the effect of this Agreement, such Parties (the “Involved Parties”) shall use their best endeavors to settle successfully such dispute, question or difference. To this effect, they shall consult and negotiate with each other, in good faith and understanding of their mutual interests, to reach an equitable solution satisfactory to the Involved Parties.

(b) If the Involved Parties do not reach a solution within a period of 30 days, then either party may submit such matter to the Court of Chancery of the State of Delaware (or in the event that such court does not have jurisdiction, to the U.S. District Court for the District of Delaware).

Section 8.03 Continuing Obligations.

Pending settlement of any dispute, the Parties shall abide by their obligations under this Agreement without prejudice to a final adjustment in accordance with an order of a court settling such dispute.

Section 8.04 Waiver of Jury Trial.

EACH MEMBER HEREBY IRREVOCABLY WAIVES THEIR RESPECTIVE RIGHTS TO JURY TRIAL OF ANY DISPUTE BASED UPON OR ARISING OUT OF THIS

 

50


AGREEMENT OR ANY OTHER AGREEMENTS RELATING HERETO OR ANY DEALINGS AMONG THEM RELATING TO THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY. The Parties each acknowledge that this waiver is a material inducement to enter into a business relationship and that they will continue to rely on the waiver in their related future dealings.

ARTICLE IX.

CONFIDENTIALITY; PUBLIC ANNOUNCEMENTS

Section 9.01 General.

Confidential Information shall not be disclosed by a Member or any of its Affiliates to any third party or the public without the prior written consent of Investor with respect to a disclosure by Sponsor Member or its Affiliates or of Sponsor Member with respect to a disclosure by Investor or its Affiliates. Company shall not disclose Confidential Information except as permitted pursuant to Section 9.02 without the Approval of the Board and the Investor.

Section 9.02 Exceptions.

The restriction imposed by Section 9.01 shall not apply to a disclosure of Confidential Information:

(a) to government agencies as required by the terms of any Governmental Authorizations;

(b) to direct or indirect equityholders, directors, officers, employees, partners (including limited partners), members, agents, and attorneys of a Party or an Affiliate of a Party who have a bona fide need to know such Confidential Information for purposes related to the disclosing Member’s interest in the Company and who have been advised of the confidential nature of such information;

(c) to any third party to whom the disclosing Member or its Affiliates lawfully contemplates a Transfer of all or any part of its interest in or to this Agreement and the Units (in accordance with the terms hereof);

(d) to a Governmental Authority or stock exchange or to the public which the disclosing Member or its Affiliates believes in good faith is required to be made by (i) any applicable Legal Requirements, (ii) any order, decree or directive of any competent judicial, legislative or regulatory body or authority applicable to the disclosing Party or its Affiliates or (iii) the rules of any relevant stock exchange or securities regulatory authority; provided that any obligation to file all or a portion of this Agreement with any securities regulatory authority shall be in accordance with Section 9.05;

(e) to (i) the Senior Lenders, (ii) any other actual or potential lenders, investors or underwriters of the disclosing Party or its Affiliates who have a bona fide need to be informed and (iii) any ratings agency that is providing or has been requested to provide a credit rating for the debt or preferred equity financing of the Project Company or any direct or indirect parent company of the Project Company or such Party or its Affiliates;

 

51


(f) to independent accountants, legal counsel or other technical or professional advisors engaged by a Party or its Affiliates for the purpose only of enabling such accountants, legal counsel or other professional advisors to give appropriate advice in respect of matters arising under this Agreement related to operations of the Company or in respect of the normal business operations of the disclosing Party or its Affiliates;

(g) to any recognized merchant or investment banking firm engaged in giving advice to the disclosing Member or its Affiliates in connection with this Agreement or in respect of the normal business operations of the disclosing Member or its Affiliates; or

(h) in connection with any legal proceeding arising in connection with this Agreement, but any such disclosure shall be subject to such confidentiality procedures as may be reasonably requested by the disclosing Party and approved by the court.

In any case involving disclosure by a Member to which Section 9.02(a), (c), (d), (e) or (g) is applicable (subject to Section 9.03 with respect to disclosures required by applicable Legal Requirements), the disclosing Member shall, except as provided in Section 9.03, give notice to Sponsor Member with respect to any disclosure by Investor or its Affiliates or to Investor with respect to any disclosure by Sponsor Member or its Affiliates, in each case, at least seven days in advance of the making of such disclosure; provided, however, that such notice shall not be required with respect to information disclosed pursuant to Section 9.02 on a regular basis in the ordinary course of business or in connection with any Permitted Upstream Transfer. Such notice shall identify the Confidential Information to be disclosed and the recipient. As to any disclosure pursuant to Section 9.02(b), (c), (e), (f) or (g), only such Confidential Information as such third party shall have a legitimate business need to know shall be disclosed. As to any disclosure pursuant to Section 9.02(a) or (d), the disclosing Member shall disclose, or permit the disclosure of, only that portion of Confidential Information required to be disclosed and shall take all reasonable steps to preserve the confidentiality thereof. As to any disclosure pursuant to Section 9.02(c), (e) or (g), such third party shall first agree in writing to protect the Confidential Information from further disclosure to the same extent as the Parties are obligated under this Article IX. Notwithstanding the absence of a required written agreement, the disclosing Party shall be responsible for assuring that no unauthorized disclosure of information to be kept confidential pursuant to Section 9.01 is made by any Person receiving information pursuant to Section 9.02(b) or (f); provided that no Party shall be liable to any other Party for the fraudulent or negligent disclosure of Confidential Information by any such Person if the Party who seeks to take the benefit of this clause shall have taken reasonable steps to ensure the preservation and confidential nature of the information.

Section 9.03 Public Announcements.

Each Member shall, in advance of making, or any of its Affiliates making, a public announcement to a stock exchange or otherwise concerning this Agreement or the Company, advise the other Member of the text of the proposed report and provide the other Member with the opportunity to comment upon the form and content thereof before the same is issued; provided, however, that a Member or an Affiliate may make a public disclosure it believes in good faith is required by applicable Legal Requirements or any listing or trading agreement concerning the publicly traded securities of its direct or indirect parent (in which case the disclosing Member will

 

52


use its reasonable best efforts to advise the other Member prior to the disclosure). If the other Member does not respond within 48 hours (excluding days that are not Business Days) or such lesser time specified as the maximum by the issuing Member or Affiliate, the announcement or report may be issued. The final text of the same and the timing, manner and mode of release shall be the sole responsibility of the issuing Member who shall indemnify, defend and hold the other Member and its Affiliates, together with Company and Company, harmless in respect of any third party claims arising therefrom.

Section 9.04 Duration of Confidentiality.

The provisions of this Article IX shall apply during the term of this Agreement and for two years following termination of this Agreement and, as to any Member who Transfers its Units in accordance with Article VII, for two years following the date of such occurrence.

Section 9.05 Redacted Filings.

If a Member determines that this Agreement is or has become a material contract that is required to be filed pursuant to applicable securities laws or other Legal Requirement, such Member covenants:

(a) to file on EDGAR, as applicable, a redacted version of this Agreement in order not to prejudicially affect the interests of the Members; and

(b) to consult with the other Members on the preparation of such redacted Agreement prior to filing.

ARTICLE X.

TERMINATION

Section 10.01 Termination of Agreement.

(a) Termination. Except as otherwise provided herein, this Agreement shall continue in full force and effect without limit until the earlier of the following events:

 

  (i)

all the Members agree in writing to terminate this Agreement;

 

  (ii)

an effective resolution is passed or a binding order is made for the winding up of Company; or

 

  (iii)

there remains only one Member;

provided, however, that this Agreement shall cease to have effect with regards to any Person who ceases to hold directly or indirectly any Units pursuant to and in accordance with the terms of this Agreement save for any provisions hereof which, expressly or by implication, are to continue in full force and effect thereafter.

(b) Winding Up. If Company is wound up by way of a voluntary winding up Approved by the Board, the Members shall procure a liquidator that is acceptable to each of the Members.

 

53


Section 10.02 Right to Data After Termination.

After termination of this Agreement by written agreement of all Parties, each Member shall be entitled to copies of all information related to the Company during the term of this Agreement not previously furnished to it, but a Member shall not be entitled to any such copies after any other termination for any other reason.

ARTICLE XI.

GENERAL PROVISIONS

Section 11.01 Notices.

All notices and other communications hereunder shall be in writing, and shall be effective (i) when personally delivered, including delivery by express courier service, (ii) on the day of receipt specified in any return receipt if it shall have been deposited in the mails or (iii) if transmitted by fax or electronic mail, on the date of transmission, in each case, to the addressee Party’s principal address stated below, whichever of the foregoing shall first occur; provided that any notice received after normal business hours at the place of delivery shall not be effective until the next Business Day at the place of delivery. Until otherwise specified by notice, the addresses for any notices shall be:

 

  (a)

If to Sponsor Member to:

Calcasieu Pass Funding, LLC

1001 19th Street North

Suite 1500

Arlington, VA 22209

Attention: Managing Member

Fax No.:  [***]

Email:   [***]

 

 

with a copy to:

Latham & Watkins LLP

885 3rd Avenue

New York, NY 10022

Attention: [***]

 

  (b)

If to Investor, to:

Stonepeak Bayou Holdings LP

c/o Stonepeak Infrastructure Partners

55 Hudson Yards

550 W 34th Street, 48th Floor

New York, NY 10001

Attention:  [***]

Email:    [***]

 

54


 

and:

Stonepeak Bayou Holdings LP

c/o Stonepeak Infrastructure Partners

55 Hudson Yards

550 W 34th Street, 48th Floor

New York, NY 10001

Attention:  [***]

Email:    [***]

 

 

with a copy to:

Simpson Thacher & Bartlett LLP

425 Lexington Avenue

New York, NY 10017

Attention:  [***]

Email:    [***]

 

  (c)

If to Company to:

Calcasieu Pass Holdings, LLC

1001 19th Street North

Suite 1500

Arlington, VA 22209

Attention: Board of Managers

Fax No.:  [***]

Email:    [***]

A Party may change its address from time to time by notice to the other Parties.

Section 11.02 Assignment.

No Party may Transfer all or any portion of its rights and/or obligations under this Agreement except in accordance with the applicable provisions hereof. Subject to the foregoing, this Agreement shall bind and inure to the benefit of the Parties and their respective successors and permitted assigns.

Section 11.03 Waiver.

Except as otherwise provided in this Agreement, failure on the part of any Party to exercise any right hereunder or to insist upon strict compliance by any other Party with any of the terms, covenants or conditions hereof shall not be deemed a waiver of such right, term, covenant or condition or limit the Party’s right thereafter to enforce any provision or exercise any right, power or remedy. No provision of this Agreement shall be construed to be a waiver by any of the Parties of any rights or remedies such Party may have against any other Party for failure to comply with the provisions of this Agreement and, except as expressly provided in this Agreement, no remedy or right herein conferred is intended to be exclusive of any other remedy or right, but every such remedy or right shall be cumulative and shall be in addition to every other remedy or right herein conferred or hereafter existing at law or in equity.

 

55


Section 11.04 Amendments.

This Agreement may not be amended or modified except by a written instrument signed by all of the Members, and Company shall be bound by any such amendment or modification. No Member shall be bound by any modification or amendment of this Agreement or waiver of any provision hereof unless such modification, amendment or waiver is set forth in a written instrument signed by each of the Members.

Section 11.05 Force Majeure.

The obligations of a Party shall be suspended to the extent and for the period that performance by such Party is prevented by any event of Force Majeure; provided that the affected Party shall give notice to the other Parties promptly, but in no event later than 30 days after the suspension of performance, stating in such notice the nature of the suspension, the reasons for the suspension and the expected duration of the suspension. The affected Party shall resume performance as soon as reasonably possible. Any time period during which performance must be achieved and as to which such performance is delayed because of Force Majeure shall be extended by a period equal to the period of suspension. Notwithstanding anything in this Section 11.05 to the contrary, an event of Force Majeure shall not excuse any payment obligation of any Party hereunder.

Section 11.06 Further Assurances.

Each Party shall take from time to time upon request of another Party, for no additional consideration, such actions and shall execute and acknowledge in form required by law for recording or registering with the proper Person and shall deliver to the requesting Party such notices, deeds or other instruments incorporating, referring to, or carrying out the provisions of this Agreement as the requesting Party may reasonably deem necessary in order to preserve or protect its interest under this Agreement or as may be reasonably necessary or convenient to implement and carry out the intent, provisions of and purpose of this Agreement.

Section 11.07 Survival of Terms and Conditions.

The provisions of this Agreement shall survive its termination to the full extent necessary for their enforcement and the protection of the Party in whose favor they run.

Section 11.08 Entire Agreement.

This Agreement, including all attached Schedules, and the Purchase Agreement contain the entire and final understanding of the Members and supersede all other prior agreements and understandings between the Members related to the subject matter of this Agreement.

 

56


Section 11.09 Severability.

Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. The validity of remaining sections, provisions, terms and parts of this Agreement shall not be affected by a court, administrative board or other proceeding of competent jurisdiction deciding that a provision, term or part of this Agreement is illegal, unenforceable, in conflict with any law or contrary to public policy. In such event the Parties shall undertake good faith efforts to amend this Agreement in order to replace such provision by a reasonable new provision or provisions which, as far as legally possible, shall approximate what the Parties intended by such original provision and the purpose thereof. Without limiting the generality of the foregoing, nothing in this Agreement shall require any Manager to act in contravention of the duties imposed on such Manager by applicable Legal Requirements.

Section 11.10 No Third-Party Beneficiary.

Except as specifically provided herein, no term or provision of this Agreement or the Schedules hereto is intended to be, or shall be construed to be, for the benefit of or enforceable by any Person, including any investment banker, broker or agent, and no such other Person shall have any right of cause of action hereunder. None of the provisions of this Agreement shall be for the benefit of, or shall be enforceable by, any creditor of the Company or any Member, other than the provisions of Section 7.02(a) and Section 7.03(d) which are for the benefit of, and may be enforced by a creditor of a Member.

Section 11.11 Time Is of the Essence.

A material consideration of the Members entering into this Agreement is that the other Members will make all contributions and other payments as and when due and will perform all other obligations under this Agreement in a timely manner. Except as otherwise specifically provided in this Agreement, time is of the essence for each and every provision of this Agreement.

Section 11.12 Limitation of Liability.

Each Party waives any claim for incidental or consequential damages hereunder, including damages for lost profits or for the speculative value or development potential of the business conducted by the Company.

Section 11.13 Counterparts.

This Agreement may be executed in any number of counterparts and by facsimile signatures, each of which when so executed and delivered shall be an original, but all the counterparts together shall constitute one and the same instrument.

[Signature Pages Follow]

 

57


IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed by their respective officers thereunto duly authorized as of the date first above written.

 

CALCASIEU PASS FUNDING, LLC
By  

/s/ D. Michael Eberhardt

 

Name: D. Michael Eberhardt

Title:  Chief Financial Officer

[Signature Page to LLC Agreement of Calcasieu Pass Holdings, LLC]


STONEPEAK BAYOU HOLDINGS LP

 

By: Stonepeak Associates III LLC, its general partner

 

By: Stonepeak GP Holdings III LP, its sole member

 

By: Stonepeak GP Investors III LLC, its general partner

 

By: Stonepeak GP Investors Manager LLC, its managing member

By:  

/s/ Jack Howell

 

Name: Jack Howell

Title:  Senior Managing Director

[Signature Page to LLC Agreement of Calcasieu Pass Holdings, LLC]


CALCASIEU PASS HOLDINGS, LLC
By  

/s/ D. Michael Eberhardt

 

Name: D. Michael Eberhardt

Title: Chief Financial Officer

[Signature Page to LLC Agreement of Calcasieu Pass Holdings, LLC]


Schedule A

Members

As of August 19, 2019

[Omitted]

08-16-2019


Schedule B

U.S. TAX PROVISIONS

[Omitted]


Schedule C

Managers

[Omitted]


Schedule D

Officers

[Omitted]


Schedule E

Form of Certificates

[Omitted]


Schedule F

Calculation of Conversion to Common Units

[Omitted]


Schedule G

Initial Budget

[Omitted]


Schedule H

Approved Sponsor Contract

[Omitted]

Exhibit 10.66

AMENDMENT NO. 1 TO

LIMITED LIABILITY COMPANY AGREEMENT

OF

CALCASIEU PASS FUNDING, LLC

This AMENDMENT NO. 1 TO LIMITED LIABILITY COMPANY AGREEMENT (this “Amendment”) of Calcasieu Pass Funding, LLC, a Delaware limited liability company (the “Company”), is entered into as of February 8, 2021 by and among the Company, Venture Global Calcasieu Pass Holding, LLC, a Delaware limited liability company (“Sponsor”), and Stonepeak Bayou Holdings II LP, a Delaware limited partnership (“Investor”). All capitalized terms used but not defined herein shall have the meanings specified in the Original LLCA (as defined below).

RECITALS

WHEREAS, the Company, Sponsor and Investor entered into that certain Limited Liability Company Agreement of the Company dated as of August 19, 2019 (the “Original LLCA”);

WHEREAS, Venture Global LNG, Inc., a Delaware corporation (“VGLNG”), as borrower, JPMorgan Chase Bank, N.A., as administrative agent and collateral agent, the Sponsor as a guarantor thereunder, the other guarantors from time to time party thereto and the banks and other financial institutions from time to time party thereto as lenders are entering into that certain Credit and Guaranty Agreement, dated on or about February 8, 2021 (as amended, restated, amended and restated, extended, supplemented, refinanced, increased or otherwise modified from time to time, the “VGLNG Term Loan”);

WHEREAS, pursuant to the VGLNG Term Loan, VGLNG and the Sponsor are providing certain collateral to the secured parties thereunder in order to secure the obligations under the VGLNG Term Loan. Such collateral includes a pledge by VGLNG of the Equity Interests of the Sponsor and a pledge by the Sponsor of the Equity Interests of the Company owned by it; and

WHEREAS, in connection with the foregoing and pursuant to Section 11.04 of the Original LLCA, Sponsor and Investor have agreed to amend the Original LLCA pursuant to this Amendment, on the terms and conditions set forth herein.

AGREEMENT

NOW, THEREFORE, in consideration of the foregoing and the respective agreements set forth herein and for other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, and intending to be legally bound, the Parties agree as follows:

1. Amendments.

(a) Section 7.03(a) of the Original LLCA is hereby amended and replaced in its entirety by the following text:


“(a) Except pursuant to Transfers permitted by Section 7.02(a) or Section 7.02(b) or any foreclosure (but excluding any subsequent Transfer) of the pledge permitted by Section 7.02(a), no Member shall directly Transfer less than all of its Units or directly Transfer its Units to a Transferee that is not just one (1) Person (or Affiliated group of Persons) without the consent of the other Member, which may be withheld or conditioned at such Member’s sole discretion. Notwithstanding anything to the contrary in this Agreement, except pursuant to Transfers permitted by Section 7.02(a) or Section 7.02(b) or any foreclosure (but excluding any subsequent Transfer) of the pledge permitted by Section 7.02(a), no direct Transfer of Units held by the Sponsor to a third-party shall be made or effective (and any purported such Transfer shall be null and void) prior to the Redemption in Full Date.”

(b) Section 6.03(b) of the Original LLCA is hereby amended by amending and restating the parenthetical at the end of subclause (iii) thereof in its entirety to read as follows:

“(in each case of the foregoing clauses (i) through (iii), other than any pledges in and of themselves (but not, for the avoidance of doubt, other than any foreclosure or other Transfer in connection with such pledges or any enforcement thereof) (A) permitted by Section 7.02(a), (B) of assets of the VGLNG (as defined in the First Amendment to this Agreement, dated as of February 8. 2021) and (C) of Equity Interests held by any direct or indirect parent of the Company that is a subsidiary of the VGLNG, in the case of each of clauses (A) through (C), to secure bona fide third party indebtedness of such Persons pursuant to the VGLNG Term Loan (as defined in the First Amendment to this Agreement, dated as of February 8, 2021)) (each such event described in clauses (i) through (iii) (as modified by the foregoing parenthetical), a “Change in Control Event”)”

2. Miscellaneous Provisions. Sections 8.01 (Governing Law), 11.01 (Notices), 11.04 (Amendments), 11.09 (Severability) and 11.13 (Counterparts) of the Original LLCA are hereby incorporated by reference in this Amendment, mutatis mutandis.

3. Full Force and Effect. Each of Parties confirms that this Amendment is intended to be a part of, and will serve as a valid, written amendment to, the Original LLCA, and each reference in the Original LLCA to “this Agreement” shall be construed to mean the Original LLCA as amended by this Amendment. Except as otherwise set forth in this Amendment, this Amendment shall not by implication or otherwise alter, modify, amend or in any way affect any of the terms, conditions, obligations, covenants or agreements contained in the Original LLCA, which are hereby ratified and affirmed in all respects and shall continue in full force and effect, and this Amendment will not operate as an extension or waiver by the parties to the Original LLCA of any other condition, covenant, obligation, right, power or privilege under the Original LLCA.

[Signature Page Follows]

 

2


IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their respective officers thereunto duly authorized as of the date first above written.

 

VENTURE GLOBAL CALCASIEU PASS HOLDING, LLC
By  

/s/ Keith Larson

Name: Keith Larson
Title: Secretary

 

STONEPEAK BAYOU HOLDINGS II LP

By: Stonepeak Associates III LLC, its general partner

By: Stonepeak GP Holdings III LP, its sole member

By: Stonepeak GP Investors III LLC, its general partner

By: Stonepeak GP Investors Manager LLC, its managing member

 

By:  

/s/ James Wyper

  Name: James Wyper
  Title: Senior Managing Director

 

CALCASIEU PASS FUNDING, LLC

By  

/s/ Keith Larson

Name: Keith Larson
Title: Secretary

[Signature to Amendment No. 1 to Funding LLCA]

Exhibit 10.67

AMENDMENT NO. 1 TO

LIMITED LIABILITY COMPANY AGREEMENT

OF

CALCASIEU PASS HOLDINGS, LLC

This AMENDMENT NO. 1 TO LIMITED LIABILITY COMPANY AGREEMENT (this “Amendment”) of Calcasieu Pass Holdings, LLC, a Delaware limited liability company (the “Company”), is entered into as of February 8, 2021 by and among the Company, Calcasieu Pass Funding, LLC, a Delaware limited liability company (“Sponsor Member”), and Stonepeak Bayou Holdings LP, a Delaware limited partnership (“Investor”). All capitalized terms used but not defined herein shall have the meanings specified in the Original LLCA (as defined below).

RECITALS

WHEREAS, the Company, Sponsor Member and Investor entered into that certain Limited Liability Company Agreement of the Company dated as of August 19, 2019 (the “Original LLCA”);

WHEREAS, the Sponsor, as borrower, JPMorgan Chase Bank, N.A., as administrative agent and collateral agent, Venture Global Calcasieu Pass Holding, LLC (“VGCPH”) as a guarantor thereunder, the other guarantors from time to time party thereto and the banks and other financial institutions from time to time party thereto as lenders are entering into that certain Credit and Guaranty Agreement, dated on or about February 8, 2021 (as amended, restated, amended and restated, extended, supplemented, refinanced, increased or otherwise modified from time to time, the “VGLNG Term Loan”);

WHEREAS, pursuant to the VGLNG Term Loan, the Sponsor and VGCPH are providing certain collateral to the secured parties thereunder in order to secure the obligations under the VGLNG Term Loan. Such collateral includes a pledge by the Sponsor of the Equity Interests of VGCPH and a pledge by VGCPH of the Equity Interests of the Sponsor Member owned by it; and

WHEREAS, in connection with the foregoing and pursuant to Section 11.04 of the Original LLCA, Sponsor Member and Investor have agreed to amend the Original LLCA pursuant to this Amendment, on the terms and conditions set forth herein.

AGREEMENT

NOW, THEREFORE, in consideration of the foregoing and the respective agreements set forth herein and for other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, and intending to be legally bound, the Parties agree as follows:

1.Amendments.

(a) Section 7.05(a) of the Original LLCA is hereby amended and replaced in its entirety by the following text:


“(a) Except (i) pursuant to Section 7.03 and, if applicable, in compliance with Section 7.04 or (ii) pursuant to Transfers permitted by Section 7.02(a) or Section 7.02(b) or any foreclosure (but excluding any subsequent Transfer) of the pledge permitted by Section 7.02(a), no Member shall directly Transfer less than all of its Common Units or directly Transfer its Common Units to a Transferee that is not just one (1) Person (or Affiliated group of Persons) without the consent of the other Member, which may be withheld or conditioned at such Member’s sole discretion. Notwithstanding anything to the contrary in this Agreement, except pursuant to Transfers permitted by Section 7.02(a) or Section 7.02(b) or any foreclosure (but excluding any subsequent Transfer) of the pledge permitted by Section 7.02(a), no direct Transfer of Units held by the Sponsor Member to a third-party shall be made or effective (and any purported such Transfer shall be null and void) prior to the Redemption Date.”

(b) Section 6.03(b) of the Original LLCA is hereby amended by amending and restating the parenthetical at the end of subclause (iii) thereof in its entirety to read as follows:

“(in each case of the foregoing clauses (i) through (iii), other than any pledges in and of themselves (but not, for the avoidance of doubt, other than any foreclosure or other Transfer in connection with such pledges or any enforcement thereof) (A) permitted by Section 7.02(a), (B) of assets of the Sponsor and (C) of Equity Interests held by any direct or indirect parent of the Company that is a subsidiary of the Sponsor, in the case of each of clauses (A) through (C), to secure bona fide third party indebtedness of such Persons pursuant to the VGLNG Term Loan (as defined in the First Amendment to this Agreement, dated as of February 8, 2021)) (each such event described in clauses (i) through (iii) (as modified by the foregoing parenthetical), a “Change in Control Event”)”

2. Miscellaneous Provisions. Sections 8.01 (Governing Law), 11.01 (Notices), 11.04 (Amendments), 11.09 (Severability) and 11.13 (Counterparts) of the Original LLCA are hereby incorporated by reference in this Amendment, mutatis mutandis.

3. Full Force and Effect. Each of Parties confirms that this Amendment is intended to be a part of, and will serve as a valid, written amendment to, the Original LLCA, and each reference in the Original LLCA to “this Agreement” shall be construed to mean the Original LLCA as amended by this Amendment. Except as otherwise set forth in this Amendment, this Amendment shall not by implication or otherwise alter, modify, amend or in any way affect any of the terms, conditions, obligations, covenants or agreements contained in the Original LLCA, which are hereby ratified and affirmed in all respects and shall continue in full force and effect, and this Amendment will not operate as an extension or waiver by the parties to the Original LLCA of any other condition, covenant, obligation, right, power or privilege under the Original LLCA.

[Signature Page Follows]

 

2


IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their respective officers thereunto duly authorized as of the date first above written.

 

CALCASIEU PASS FUNDING, LLC

 

By  

/s/ Keith Larson

Name: Keith Larson
Title: Secretary

 

STONEPEAK BAYOU HOLDINGS LP

 

By: Stonepeak Associates III LLC, its general partner

 

By: Stonepeak GP Holdings III LP, its sole member

 

By: Stonepeak GP Investors III LLC, its general partner

 

By: Stonepeak GP Investors Manager LLC, its managing member

 

By:  

/s/ James Wyper

  Name: James Wyper
  Title: Senior Managing Director

 

CALCASIEU PASS HOLDINGS, LLC
By  

/s/ Keith Larson

Name: Keith Larson
Title: Secretary

[Signature to Amendment No. 1 to Holdings LLCA]

Exhibit 10.68

Execution Copy

AMENDMENT NO. 2 TO

LIMITED LIABILITY COMPANY AGREEMENT

OF

CALCASIEU PASS FUNDING, LLC

This AMENDMENT NO. 2 TO LIMITED LIABILITY COMPANY AGREEMENT (this “Amendment”) of Calcasieu Pass Funding, LLC, a Delaware limited liability company (the “Company”), is entered into as of October 27, 2021 by and among the Company, Venture Global Calcasieu Pass Holding, LLC, a Delaware limited liability company (“Sponsor”), and Stonepeak Bayou Holdings II LP, a Delaware limited partnership (“Investor”). All capitalized terms used but not defined herein shall have the meanings specified in the LLCA (as defined below).

RECITALS

WHEREAS, the Company, Sponsor and Investor entered into that certain Limited Liability Company Agreement of the Company dated as of August 19, 2019, as amended on February 8, 2021 (the “LLCA”); and

WHEREAS, pursuant to Section 11.04 of the LLCA, Sponsor and Investor have agreed to amend the LLCA pursuant to this Amendment, on the terms and conditions set forth herein.

AGREEMENT

NOW, THEREFORE, in consideration of the foregoing and the respective agreements set forth herein and for other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, and intending to be legally bound, the Parties agree as follows:

1. Amendments.

(a) The definition of Permitted Upstream Transfer in Article I is hereby amended by replacing subsection (b)(iii) with the following, without modifying the proviso that follows subsection (b)(iii):

“(iii) any Transfer of equity securities of VGLNG (as defined in Amendment No. 1 to this Agreement dated February 8, 2021),”

(b) Section 6.03(b) of the LLCA is hereby amended by adding the words “or VGLNG” in each place after “or Sponsor” in the first sentence thereof and amending and restating the parenthetical at the end of subclause (iii) thereof in its entirety to read as follows:

“(in each case of the foregoing clauses (i) through (iii), other than any pledges in and of themselves (but not, for the avoidance of doubt, any foreclosure or other Transfer in connection with such pledges or any enforcement thereof) (A) permitted by Section 7.02(a), (B) of assets of VGLNG (as defined in Amendment No. 1 to this Agreement dated February 8, 2021) and (C) of Equity Interests held by any


direct or indirect parent of the Company that is a subsidiary of VGLNG, (x) in the case of each of clauses (A) through (C), to secure bona fide third party indebtedness of such Persons pursuant to the VGLNG Term Loan (as defined in Amendment No. 1 to this Agreement, dated as of February 8, 2021) or (y) in the case of any Transfer of equity interests of VGLNG described in Clause (A), to secure bona fide third party indebtedness of Venture Global Partners, LLC (as a holder of equity interests of VGLNG) and Venture Global Commodities, LLC, VGLNG or any direct or indirect parent of the Company that is a subsidiary of VGLNG)) (each such event described in clauses (i) through (iii) (as modified by the foregoing parenthetical), a “Change in Control Event”)”.

(c) Section 7.02(a) of the LLCA is hereby amended by adding the words “directly or indirectly” immediately preceding the words “pledged to secure bona fide third party indebtedness”.

2. Miscellaneous Provisions. Sections 8.01 (Governing Law), 11.01 (Notices), 11.04 (Amendments), 11.09 (Severability) and 11.13 (Counterparts) of the LLCA are hereby incorporated by reference in this Amendment, mutatis mutandis.

3. Full Force and Effect. Each of Parties confirms that this Amendment is intended to be a part of, and will serve as a valid, written amendment to, the LLCA, and each reference in the LLCA to “this Agreement” shall be construed to mean the LLCA as amended by this Amendment. Except as otherwise set forth in this Amendment, this Amendment shall not by implication or otherwise alter, modify, amend or in any way affect any of the terms, conditions, obligations, covenants or agreements contained in the LLCA, which are hereby ratified and affirmed in all respects and shall continue in full force and effect, and this Amendment will not operate as an extension or waiver by the parties to the LLCA of any other condition, covenant, obligation, right, power or privilege under the LLCA.

[Signature Page Follows]

 

2


IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their respective officers thereunto duly authorized as of the date first above written.

 

VENTURE GLOBAL CALCASIEU PASS HOLDING, LLC

 

By  

/s/ Keith Larson

Name: Keith Larson
Title: Secretary

 

STONEPEAK BAYOU HOLDINGS II LP

 

By: Stonepeak Associates III LLC, its general partner

 

By: Stonepeak GP Holdings III LP, its sole member

 

By: Stonepeak GP Investors III LLC, its general partner

 

By: Stonepeak GP Investors Manager LLC, its managing member

 

By:  

/s/ James Wyper

  Name: James Wyper
  Title: Senior Managing Director

 

CALCASIEU PASS FUNDING, LLC

 

By  

/s/ Keith Larson

Name: Keith Larson
Title: Secretary

[Signature to Amendment No. 2 to Funding LLCA]

Exhibit 10.69

Execution Copy

AMENDMENT NO. 2 TO

LIMITED LIABILITY COMPANY AGREEMENT

OF

CALCASIEU PASS HOLDINGS, LLC

This AMENDMENT NO. 2 TO LIMITED LIABILITY COMPANY AGREEMENT (this “Amendment”) of Calcasieu Pass Holdings, LLC, a Delaware limited liability company (the “Company”), is entered into as of October 27, 2021 by and among the Company, Calcasieu Pass Funding, LLC, a Delaware limited liability company (“Sponsor Member”), and Stonepeak Bayou Holdings LP, a Delaware limited partnership (“Investor”). All capitalized terms used but not defined herein shall have the meanings specified in the LLCA (as defined below).

RECITALS

WHEREAS, the Company, Sponsor Member and Investor entered into that certain Limited Liability Company Agreement of the Company dated as of August 19, 2019, as amended on February 8, 2021 (the “LLCA”); and

WHEREAS, pursuant to Section 11.04 of the LLCA, Sponsor Member and Investor have agreed to amend the LLCA pursuant to this Amendment, on the terms and conditions set forth herein.

AGREEMENT

NOW, THEREFORE, in consideration of the foregoing and the respective agreements set forth herein and for other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, and intending to be legally bound, the Parties agree as follows:

1. Amendment.

(a) Section 6.03(b) of the LLCA is hereby amended by amending and restating the parenthetical at the end of subclause (iii) thereof in its entirety to read as follows:

“(in each case of the foregoing clauses (i) through (iii), other than any pledges in and of themselves (but not, for the avoidance of doubt, any foreclosure or other Transfer in connection with such pledges or any enforcement thereof) (A) permitted by Section 7.02(a), (B) of assets of the Sponsor and (C) of Equity Interests held by any direct or indirect parent of the Company that is a subsidiary of the Sponsor, (x) in the case of each of clauses (A) through (C), to secure bona fide third party indebtedness of such Persons pursuant to the VGLNG Term Loan (as defined in the Amendment No. 1 to this Agreement, dated as of February 8, 2021) or (y) in the case of any Transfer of equity interests of Sponsor described in Clause (A), to secure bona fide third party indebtedness of Venture Global Partners, LLC (as a holder of equity interests of the Sponsor) and Venture Global Commodities, LLC, the Sponsor or any direct or indirect parent of the Company that is a subsidiary of the Sponsor)) (each such event described in clauses (i) through (iii) (as modified by the foregoing parenthetical), a “Change in Control Event”)”.


(b) Section 7.02(a) of the LLCA is hereby amended by adding the words “directly or indirectly” immediately preceding the words “pledged to secure bona fide third party indebtedness”.

2. Miscellaneous Provisions. Sections 8.01 (Governing Law), 11.01 (Notices), 11.04 (Amendments), 11.09 (Severability) and 11.13 (Counterparts) of the LLCA are hereby incorporated by reference in this Amendment, mutatis mutandis.

3. Full Force and Effect. Each of Parties confirms that this Amendment is intended to be a part of, and will serve as a valid, written amendment to, the LLCA, and each reference in the LLCA to “this Agreement” shall be construed to mean the LLCA as amended by this Amendment. Except as otherwise set forth in this Amendment, this Amendment shall not by implication or otherwise alter, modify, amend or in any way affect any of the terms, conditions, obligations, covenants or agreements contained in the LLCA, which are hereby ratified and affirmed in all respects and shall continue in full force and effect, and this Amendment will not operate as an extension or waiver by the parties to the LLCA of any other condition, covenant, obligation, right, power or privilege under the LLCA.

[Signature Page Follows]

 

2


IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their respective officers thereunto duly authorized as of the date first above written.

 

CALCASIEU PASS FUNDING, LLC

 

By

 

 

/s/ Keith Larson

Name: Keith Larson
Title: Secretary

 

STONEPEAK BAYOU HOLDINGS LP

By: Stonepeak Associates III LLC, its general partner

By: Stonepeak GP Holdings III LP, its sole member

By: Stonepeak GP Investors III LLC, its general partner

By: Stonepeak GP Investors Manager LLC, its managing member

 

By:  

/s/ James Wyper

  Name: James Wyper
  Title: Senior Managing Director

 

CALCASIEU PASS HOLDINGS, LLC

 

By

 

 

/s/ Keith Larson

Name: Keith Larson
Title: Secretary

[Signature to Amendment No. 2 to Holdings LLCA]

Exhibit 10.70

Execution Version

AMENDMENT NO. 3 TO

LIMITED LIABILITY COMPANY AGREEMENT

OF

CALCASIEU PASS FUNDING, LLC

This AMENDMENT NO. 3 TO LIMITED LIABILITY COMPANY AGREEMENT (this “Amendment”) of Calcasieu Pass Funding, LLC, a Delaware limited liability company (the “Company”), is entered into as of July 30, 2022 by and among the Company, Venture Global Calcasieu Pass Holding, LLC, a Delaware limited liability company (“Sponsor”), and Stonepeak Bayou Holdings II LP, a Delaware limited partnership (“Investor”). All capitalized terms used but not defined herein shall have the meanings specified in the LLCA (as defined below).

RECITALS

WHEREAS, the Company, Sponsor and Investor entered into that certain Limited Liability Company Agreement of the Company dated as of August 19, 2019, as amended on February 8, 202 I, and as further amended on October 27, 2021 (the “LLCA”); and

WHEREAS, pursuant to Section 11.04 of the LLCA, Sponsor and Investor have agreed to amend the LLCA pursuant to this Amendment, on the terms and conditions set forth herein.

AGREEMENT

NOW, THEREFORE, in consideration of the foregoing and the respective agreements set forth herein and for other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, and intending to be legally bound, the Parties agree as follows:

1. Amendments.

(a) Section 1.01 (Definitions) is hereby amended by adding the following in alphabetical order:

“Monthly Distribution Date” means, solely with respect to Net LNG Sales Proceeds, the distribution date established by the Managing Member as promptly as practicable following the last day of each calendar month (which shall, in any case, occur no later than thirty (30) days following the last day of such calendar month).”

(b) Section 6.02(a) of the LLCA is hereby amended and restated in its entirety to read as follows:

“(a) For each full month ending on or prior to the Commercial Operation Date, distributions on Common Units shall be paid from Net LNG Sales Proceeds on each Monthly Distribution Date following such declaration by the Managing Member to the Members holding Common Units as they appear on Schedule A at the close of business on the relevant record date for such distribution.”


2.  Miscellaneous Provisions. Sections 8.01 (Governing Law), 11.01 (Notices), 11.04 (Amendments), 11.09 (Severability) and 11.13 (Counterparts) of the LLCA are hereby incorporated by reference in this Amendment, mutatis mutandis.

3.  Full Force and Effect. Each of Parties confirms that this Amendment is intended to be a part of, and will serve as a valid, written amendment to, the LLCA, and each reference in the LLCA to “this Agreement” shall be construed to mean the LLCA as amended by this Amendment. Except as otherwise set forth in this Amendment, this Amendment shall not by implication or otherwise alter, modify, amend or in any way affect any of the terms, conditions, obligations, covenants or agreements contained in the LLCA, which are hereby ratified and affirmed in all respects and shall continue in full force and effect, and this Amendment will not operate as an extension or waiver by the parties to the LLCA of any other condition, covenant, obligation, right, power or privilege under the LLCA.

[Signature Page Follows]

 

2


IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their respective officers thereunto duly authorized as of the date first above written.

 

VENTURE GLOBAL CALCASIEU PASS HOLDING, LLC

 

By:  

/s/ Keith Larson

Name:   Keith Larson
Title:  

Secretary

 

STONEPEAK BAYOU HOLDINGS II LP

By:   Stonepeak Associates III LLC, its general partner
By:   Stonepeak GP Holdings III LP, its sole member
By:   Stonepeak GP Investors III LLC, its general partner
By:  

Stonepeak GP Investors Manager LLC, its managing member

 

By:  

/s/ James Wyper

Name:  

James Wyper

Title:  

Senior Managing Director

 

CALCASIEU PASS FUNDING, LLC

 

By:  

/s/ Keith Larson

Name:  

Keith Larson

Title:  

Secretary

[Signature to Amendment No. 3 to Funding LLCA]

Exhibit 10.71

Execution Version

AMENDMENT NO. 3 TO

LIMITED LIABILITY COMPANY AGREEMENT

OF

CALCASIEU PASS HOLDINGS, LLC

This AMENDMENT NO. 3 TO LIMITED LIABILITY COMPANY AGREEMENT (this “Amendment”) of Calcasieu Pass Holdings, LLC, a Delaware limited liability company (the “Company”), is entered into as of July 30, 2022 by and among the Company, Calcasieu Pass Funding, LLC, a Delaware limited liability company (“Sponsor Member”), and Stonepeak Bayou Holdings LP, a Delaware limited partnership (“Investor”). All capitalized terms used but not defined herein shall have the meanings specified in the LLCA (as defined below).

RECITALS

WHEREAS, the Company, Sponsor Member and Investor entered into that certain Limited Liability Company Agreement of the Company dated as of August 19, 2019, as amended on February 8, 2021, and as further amended on October 27, 2021 (the “LLCA”); and

WHEREAS, pursuant to Section 11.04 of the LLCA, Sponsor Member and Investor have agreed to amend the LLCA pursuant to this Amendment, on the terms and conditions set forth herein.

AGREEMENT

NOW, THEREFORE, in consideration of the foregoing and the respective agreements set forth herein and for other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, and intending to be legally bound, the Parties agree as follows:

1. Amendments.

(a) Section 1.01 (Definitions) is hereby amended by adding the following in alphabetical order:

‘‘‘‘Monthly Distribution Date” means, solely with respect to Net LNG Sales Proceeds, the distribution date established by the Board as promptly as practicable following the last day of each calendar month (which shall, in any case, occur no later than thirty (30) days following the last day of such calendar month).”

(b) Section 6.02(a) of the LLCA is hereby amended and restated in its entirety to read as follows:

“(a) For each full month ending on or prior to the Conversion Date, distributions on Class A Units shall be paid from Net LNG Sales Proceeds on each Monthly Distribution Date following such declaration by the Board to the Members holding Class A Units as they appear on Schedule A at the close of business on the relevant record date for such distribution.”


2. Miscellaneous Provisions. Sections 8.01 (Governing Law), 11.01 (Notices), 11.04 (Amendments), 11.09 (Severability) and 11.13 (Counterparts) of the LLCA are hereby incorporated by reference in this Amendment, mutatis mutandis.

3. Full Force and Effect. Each of Parties confirms that this Amendment is intended to be a part of, and will serve as a valid, written amendment to, the LLCA, and each reference in the LLCA to “this Agreement” shall be construed to mean the LLCA as amended by this Amendment. Except as otherwise set forth in this Amendment, this Amendment shall not by implication or otherwise alter, modify, amend or in any way affect any of the terms, conditions, obligations, covenants or agreements contained in the LLCA, which are hereby ratified and affirmed in all respects and shall continue in full force and effect, and this Amendment will not operate as an extension or waiver by the parties to the LLCA of any other condition, covenant, obligation, right, power or privilege under the LLCA.

[Signature Page Follows]

 

2


IN WITNESS WHEREOF, the Parties have caused this Amendment to be executed by their respective officers thereunto duly authorized as of the date first above written.

 

CALCASIEU PASS FUNDING, LLC
By  

/s/ Keith Larson

Name:   Keith Larson
Title:   Secretary

 

STONEPEAK BAYOU HOLDINGS LP

By: Stonepeak Associates III LLC, its general partner

By: Stonepeak GP Holdings III LP, its sole member

By: Stonepeak GP Investors III LLC, its general partner

By: Stonepeak GP Investors Manager LLC, its managing member

 

By:  

/s/ James Wyper

  Name: James Wyper
  Title: Senior Managing Director

 

CALCASIEU PASS HOLDINGS, LLC
By  

/s/ Keith Larson

Name: Keith Larson
Title:  Secretary

[Signature to Amendment No. 3 to Holdings LLCA]

Exhibit 10.72

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

 

 

Execution Version

CREDIT FACILITY AGREEMENT

 

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as Borrower,

 

 

TRANSCAMERON PIPELINE, LLC,

as Guarantor,

 

 

THE LENDERS PARTY HERETO FROM TIME TO TIME,

as Lenders,

THE ISSUING BANKS HERETO FROM TIME TO TIME,

as Issuing Banks,

and

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

and

solely for purposes of Section 3.06,

MIZUHO BANK (USA),

as Collateral Agent

 

 

Dated as of August 19, 2019


TABLE OF CONTENTS

 

         Page  

ARTICLE I DEFINITIONS AND INTERPRETATION

     2  

Section 1.01

  Defined Terms      2  

Section 1.02

  Principles of Interpretation      2  

Section 1.03

  UCC Terms      2  

Section 1.04

  Accounting and Financial Determinations      2  

Section 1.05

  Designations      2  

ARTICLE II COMMITMENTS AND ADVANCES

     3  

Section 2.01

  Term Loans      3  

Section 2.02

  Term Loan Availability      4  

Section 2.03

  Working Capital Loans      4  

Section 2.04

  Working Capital Loan Availability      5  

Section 2.05

  Procedures for Requesting Advances      6  

Section 2.06

  Funding      8  

Section 2.07

  Termination or Reduction of Commitments      10  

Section 2.08

  [Reserved]      12  

Section 2.09

  Incremental Commitments      12  

Section 2.10

  Use of Proceeds      13  

ARTICLE III LETTERS OF CREDIT

     14  

Section 3.01

  Letters of Credit      14  

Section 3.02

  Reimbursement to Issuing Banks      18  

Section 3.03

  Obligations Absolute      20  

Section 3.04

  Liability of the Issuing Banks and the Working Capital Lenders      20  

Section 3.05

  Resignation as an Issuing Bank      21  

Section 3.06

  Non-Fronted Letters of Credit      21  

Section 3.07

  Reinstatement of Letters of Credit      22  

ARTICLE IV REPAYMENTS, PREPAYMENTS, INTEREST AND FEES

     22  

Section 4.01

  Repayment of Term Loan Advances      22  

Section 4.02

  Repayment of LC Loans      23  

Section 4.03

  Repayment of Working Capital Advances      23  

Section 4.04

  Interest Payment Dates      23  

Section 4.05

  Interest Rates      24  

Section 4.06

  Conversion Options      25  

Section 4.07

  Post-Maturity Interest Rates; Default Interest Rates      25  

Section 4.08

  Interest Rate Determination      25  

Section 4.09

  Computation of Interest and Fees      26  

Section 4.10

  Terms of All Prepayments      26  

Section 4.11

  Voluntary Prepayment      26  

 

i


Section 4.12

  Mandatory Prepayment      27  

Section 4.13

  Time and Place of Payments      28  

Section 4.14

  Advances and Payments Generally      29  

Section 4.15

  Fees      29  

Section 4.16

  Pro Rata Treatment      30  

Section 4.17

  Sharing of Payments      31  

Section 4.18

  Defaulting Lenders      32  

ARTICLE V LIBOR AND TAX PROVISIONS

     34  

Section 5.01

  LIBOR Lending Unlawful      34  

Section 5.02

  Inability to Determine LIBOR      34  

Section 5.03

  Increased Costs      35  

Section 5.04

  Obligation to Mitigate      36  

Section 5.05

  Funding Losses      36  

Section 5.06

  Taxes      37  

Section 5.07

  Effect of Benchmark Transition Event      37  

ARTICLE VI REPRESENTATIONS AND WARRANTIES

     38  

Section 6.01

  Incorporation of Common Terms Agreement      38  

ARTICLE VII CONDITIONS PRECEDENT

     38  

Section 7.01

  Conditions to Closing      38  

Section 7.02

  Conditions to Each Term Loan Advance      38  

Section 7.03

  Conditions to Each Working Capital Advance      38  

Section 7.04

  Conditions to Occurrence of the Project Completion Date      39  

ARTICLE VIII COVENANTS

     39  

Section 8.01

  Covenants      39  

ARTICLE IX DEFAULT AND ENFORCEMENT

     39  

Section 9.01

  Events of Default      39  

Section 9.02

  Acceleration Upon Bankruptcy      39  

Section 9.03

  Action Upon Event of Default      40  

Section 9.04

  Cash Collateralization of Letters of Credit.      41  

Section 9.05

  Application of Proceeds      41  

ARTICLE X THE CREDIT FACILITY AGENT

     41  

Section 10.01

  Appointment and Authority      41  

Section 10.02

  Rights as a Facility Lender or Hedging Bank      43  

Section 10.03

  Exculpatory Provisions      43  

Section 10.04

  Reliance by Credit Facility Agent      45  

Section 10.05

  Delegation of Duties      45  

 

ii


Section 10.06

  Indemnification by the Lenders      46  

Section 10.07

  Resignation or Removal of Credit Facility Agent      46  

Section 10.08

  No Amendment to Duties of Credit Facility Agent Without Consent      48  

Section 10.09

  Non-Reliance on Credit Facility Agent, Lenders      48  

Section 10.10

  No Initial Coordinating Lead Arranger, Coordinating Lead Arranger or Documentation Bank Duties      48  

Section 10.11

  Copies      48  

Section 10.12

  General Provisions as to Payments      49  

Section 10.13

  Agreement to Comply with Finance Documents      49  

ARTICLE XI MISCELLANEOUS PROVISIONS

     50  

Section 11.01

  Decisions; Amendments, Etc.      50  

Section 11.02

  Entire Agreement      53  

Section 11.03

  Applicable Government Rule; Jurisdiction; Etc.      53  

Section 11.04

  Assignments      54  

Section 11.05

  Benefits of Agreement      60  

Section 11.06

  Counterparts; Effectiveness      60  

Section 11.07

  Indemnification by the Borrower      60  

Section 11.08

  Interest Rate Limitation      61  

Section 11.09

  No Waiver; Cumulative Remedies      61  

Section 11.10

  Notices and Other Communications      61  

Section 11.11

  USA Patriot Act Notice      62  

Section 11.12

  Payments Set Aside      62  

Section 11.13

  Right of Set-Off      63  

Section 11.14

  Severability      63  

Section 11.15

  Survival      63  

Section 11.16

  Treatment of Certain Information; Confidentiality      64  

Section 11.17

  Waiver of Consequential Damages, Etc.      64  

Section 11.18

  Waiver of Litigation Payments      64  

Section 11.19

  Reinstatement      64  

Section 11.20

  No Recourse      64  

Section 11.21

  Intercreditor Agreement      65  

Section 11.22

  Termination      65  

Section 11.23

  Acknowledgment and Consent to Bail-In of EEA Financial Institutions      65  

 

SCHEDULES

Schedule I

  - Lenders, Commitments

Schedule II

  - Issuing Bank Limits

Schedule III

  - Amortization Schedule

Schedule IV

  - Credit Facility Agent Account Details

 

iii


EXHIBITS

Exhibit A

  - Definitions

Exhibit B-1

  - Form of Term Loan Note

Exhibit B-2

  - Form of Working Capital Note

Exhibit C

  - [Reserved]

Exhibit D

  - [Reserved]

Exhibit E-1

  - Form of Letter of Credit – TETCO

Exhibit E-2

  - Form of Letter of Credit – ANR

Exhibit E-3

  - Form of Letter of Credit – EnLink

Exhibit F

  - Form of Interest Period Notice

Exhibit G

  - Form of Lender Assignment Agreement

 

iv


CREDIT FACILITY AGREEMENT

This CREDIT FACILITY AGREEMENT, dated as of August 19, 2019 (the “Credit Facility Agreement” or this “Agreement”), is made among:

VENTURE GLOBAL CALCASIEU PASS, LLC, a limited liability company organized under the laws of the State of Delaware (the “Borrower”),

TRANSCAMERON PIPELINE, LLC, a limited liability company organized under the laws of the State of Delaware (the “Guarantor”),

NATIXIS, NEW YORK BRANCH, in its capacity as administrative agent for the Lenders and Issuing Banks hereunder (and, together with each other Person that may, from time to time, be appointed as successor Credit Facility Agent in accordance with Section 10.07 (Resignation or Removal of Credit Facility Agent), the “Credit Facility Agent”),

Solely for purposes of Section 3.06, MIZUHO BANK (USA), as the Collateral Agent (the “Collateral Agent”),

Each of the Issuing Banks party hereto from time to time, and

Each of the Lenders party hereto from time to time.

WHEREAS, the Borrower intends to engage in the Development;

WHEREAS, the Borrower has requested that (i) the Working Capital Lenders and the Issuing Banks establish a working capital credit facility in order to provide loans and letters of credit which are to be used by, or otherwise be issued for the account of, the Obligors, as set forth herein and in the other Finance Documents (the “Working Capital Facility”) and (ii) the Term Lenders establish a credit facility in order to provide funds which are to be used to partially finance the Development through the payment of Project Costs and otherwise, as set forth herein and in the other Finance Documents;

WHEREAS, pursuant to that certain Assignment of Intercompany Loan Agreement, dated as of the date hereof, by and between the Borrower, the Guarantor, the Sponsor and the Credit Facility Agent, the Sponsor has assigned to the Credit Facility Agent all of its right, title and interest in and to that certain Intercompany Loan Agreement, dated as of March 29, 2019, by and between the Sponsor, as lender, and the Borrower, as Borrower (the “Intercompany Loan Agreement”), and the loans to the Borrower made thereunder in the principal amount of up to $150,000,000; and

WHEREAS, the Borrower, the Guarantor, the Credit Facility Agent, Working Capital Lenders, the Issuing Banks, the Term Lenders and, solely for purposes of Section 3.06 hereof, desire to amend and restate the Intecompany Loan Agreement to make such credit facilities available upon and subject to the terms and conditions hereinafter set forth.


NOW THEREFORE, in consideration of the foregoing, and for other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, the parties hereto hereby amend and restate the Intercompany Loan Agreement in its entirety and agree as follows:

ARTICLE I

DEFINITIONS AND INTERPRETATION

Section 1.01 Defined Terms. Unless otherwise defined in Exhibit A, capitalized terms used in this Agreement (including the preamble hereto) shall have the meanings provided in Section 1.3 (Definitions) of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement.

Section 1.02 Principles of Interpretation. Unless otherwise provided herein, this Agreement shall be governed by the principles of interpretation provided in Section 1.2 (Interpretation) of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement, mutatis mutandis.

Section 1.03 UCC Terms. Unless otherwise defined herein or in Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement, terms used herein that are defined in the UCC shall have the respective meanings given to those terms in the UCC.

Section 1.04 Accounting and Financial Determinations. Except as otherwise expressly provided herein, all terms of an accounting or financial nature shall be construed in accordance with GAAP, as in effect from time to time; provided, that, if the Borrower notifies the Intercreditor Agent and the Credit Facility Agent that the Borrower requests an amendment to any provision hereof to eliminate the effect of any change occurring after the Closing Date in GAAP or in the application thereof on the operation of, or calculation of compliance with, such provision so as to preserve the original intent thereof in light of such change in GAAP (or if the Intercreditor Agent and Credit Facility Agent, as the case may be, notifies the Borrower that the Required Lenders request an amendment to any provision hereof for such purpose), regardless of whether any such notice is given before or after such change in GAAP or in the application thereof, then such provision shall be interpreted on the basis of GAAP as in effect and applied immediately before such change shall have become effective until such provision has been amended in accordance herewith.

Section 1.05 Designations. This Agreement is a Facility Agreement and a Senior Debt Instrument, the Term Lenders, Working Capital Lenders and Issuing Banks in this Agreement are Senior Creditors and the Credit Facility Agent is the Senior Creditor Group Representative of the Term Lenders, the Working Capital Lenders and the Issuing Banks, in each case under the Finance Documents.

 

2


ARTICLE II

COMMITMENTS AND ADVANCES

On the terms, subject to the conditions and relying upon the representations and warranties herein set forth:

Section 2.01 Term Loans. (a) Each Term Lender, severally and not jointly, shall make Term Loans to the Borrower: (i) in an aggregate principal amount not in excess of the Base Term Loan Commitments of such Term Lender, if any, from time to time during the Term Loan Availability Period but not more frequently than as permitted under Section 2.05 (Procedures for Requesting Advances) for use in accordance with Section 2.10(a)(i) (Use of Proceeds); and (ii) in an aggregate principal amount not in excess of the Contingency Reserve Term Loan Commitments of such Term Lender, if any, from time to time during the Term Loan Availability Period but not more frequently than as permitted under Section 2.05 (Procedures for Requesting Advances) for use in accordance with Section 2.10(a)(ii) (Use of Proceeds); provided that, after giving effect to the making of any Term Loans, the aggregate outstanding principal amount of all Term Loans shall not exceed the Aggregate Term Loan Commitments. The aggregate amount of the Base Term Loan Commitments as of the Closing Date is $[***], and the aggregate amount of the Contingency Reserve Term Loan Commitments as of the Closing Date is $[***].

(b) Each Term Loan Advance shall be in an amount specified in the relevant Disbursement Request.

(c) Except as set forth in clause (d) below, proceeds of the Term Loans shall be deposited into the Construction Account in accordance with Section 4.5(a) (Deposits and Withdrawals – Disbursements of Senior Debt) of the Common Security and Account Agreement. The Obligors shall not request or apply any portion of any Term Loan other than in accordance with this Section 2.1 (Term Loans), Sections 2.02 (Term Loan Availability) and 2.10 (Use of Proceeds) of this Agreement and Sections 2.3 (Disbursement Procedures), 2.4 (Pro Rata Advances), 2.6 (Currency) and 12.1 (Use of Proceeds) of the Common Terms Agreement. Neither the Credit Facility Agent nor the Term Lenders are under any obligation hereunder to inquire into or verify the application of any Term Loan but this does not affect or limit the Obligors’ obligations hereunder or under the Common Terms Agreement.

(d) Notwithstanding Section 2.01(c), proceeds of the Term Loans funded from the Contingency Reserve Term Loan Commitment (including as such proceeds may be used to fund the Contingency Reserve Account on the Project Completion Date (as specified in Section 14.2(b) (Project Completion Date Waterfall – Final Advance of Term Loans) of the Common Terms Agreement)) shall be paid into the Contingency Reserve Account in accordance with Section 4.5(k) (Deposits and Withdrawals – Contingency Reserve Account) of the Common Security and Account Agreement; provided that such transfer shall occur on the same day that the Credit Facility Agent receives such proceeds from the Term Lenders and subject to the Credit Facility Agent’s actual receipt of such proceeds in accordance with Section 2.06(a) (Funding). For the avoidance of doubt, such Advances shall constitute a Term Loan for all purposes under this Agreement and each other Finance Document and shall be treated as received, and accounted for as a Term Loan, by the Borrower.

 

3


(e) Term Loans that are repaid or prepaid may not be reborrowed.

Section 2.02 Term Loan Availability. (a) Subject to the terms and conditions set forth in this Agreement and the Common Terms Agreement, each Term Lender severally, and not jointly or jointly and severally, agrees to advance to the Borrower its pro rata share of such Term Lender’s Term Loan Commitment as the Borrower may request under this Section 2.02 (Term Loan Availability) and the applicable Disbursement Request (each such Advance when made, individually, a “Term Loan” and, collectively, the “Term Loans”), in an aggregate principal amount not to exceed such Term Lender’s Term Loan Commitment, from time to time during the period commencing (solely with respect to the Initial Advance) on the Closing Date and (with respect to all other Advances of Term Loans) following the utilization in full of both the Closing Date Equity Funding and the Initial Advance, and ending on the earliest of (such period, the “Term Loan Availability Period”):

  (i) the Date Certain;

 (ii) the Project Completion Date;

(iii) the date the Term Loan Commitments are fully utilized or of any cancellation or termination of all of the remaining Term Loan Commitments pursuant to Section 3.8 (Reductions and Cancellations of Facility Commitments) of the Common Terms Agreement; and

(iv) the date the Required Lenders terminate their Commitments upon the occurrence and during the Continuance of a Loan Facility Event of Default.

(b) Subject to Section 2.2 (Sequence of Advances of Initial Senior Debt) of the Common Terms Agreement, Section 2.4 (Pro Rata Advances) of the Common Terms Agreement and the applicable conditions of Article 4 (Conditions Precedent) of the Common Terms Agreement and Section 2.02(a) (Term Loan Availability) of this Agreement, the Borrower shall be entitled to draw down all or a portion of the unused Term Loan Commitments before or on the final date of the Term Loan Availability Period for the purposes set forth in Section 12.1 (Use of Proceeds) of the Common Terms Agreement and Section 2.10 (Use of Proceeds) of this Agreement.

Section 2.03 Working Capital Loans. (a) Each Working Capital Lender, severally and not jointly, shall make Working Capital Loans to the Borrower in an aggregate principal amount not in excess of its Working Capital Commitment from time to time during the Working Capital Loan Availability Period; provided that, after giving effect to the making of any Working Capital Loans, (i) the aggregate Working Capital Commitment Exposure for all Working Capital Lenders shall not exceed the Aggregate Working Capital Commitments and (ii) no Working Capital Lender shall be required to make any Working Capital Loan if such Working Capital Lender’s Working Capital Commitment Exposure would exceed its Working Capital Commitment.

 

4


(b) Each Working Capital Advance shall be in an amount specified in the relevant Disbursement Request.

(c) Proceeds of the Working Capital Loans shall be deposited or applied in accordance with Section 4.5(a) (Deposits and Withdrawals – Disbursements of Senior Debt) of the Common Security and Account Agreement. The Obligors shall not request or apply any portion of any Working Capital Loan other than in accordance with this Section 2.03 (Working Capital Loans), Sections 2.04 (Working Capital Loan Availability) and 2.10 (Use of Proceeds) and Section 2.3 (Disbursement Procedures) and Section 2.6 (Currency) of the Common Terms Agreement. Neither the Credit Facility Agent nor the Working Capital Lenders are under any obligation hereunder to inquire into or verify the application of any Working Capital Loan but this does not affect or limit any Obligor’s obligations hereunder or under the Common Terms Agreement.

(d) [Reserved].

(e) Working Capital Loans repaid or prepaid, except in accordance with Sections 4.12(b)(ii), (iii) and (iv) (Mandatory Prepayment), may be re-borrowed at any time and from time to time up to but excluding the Working Capital Loan Termination Date. Each Working Capital Lender’s Working Capital Commitment shall expire on the Working Capital Loan Termination Date and all other amounts owed hereunder with respect to Working Capital Loans and the Working Capital Commitments shall be paid in full no later than such date.

Section 2.04 Working Capital Loan Availability. (a) Subject to the terms and conditions set forth in this Agreement and the Common Terms Agreement, each Working Capital Lender severally, and not jointly or jointly and severally, agrees to make Advances to the Borrower in the amount of its Commitment Percentage of the amount the Borrower may request, in accordance with this Section 2.04 (Working Capital Loan Availability) and the applicable Disbursement Request (each such Advance, when made, individually, a “Working Capital Loan” and, collectively, the “Working Capital Loans”), in an aggregate principal amount not to exceed such Working Capital Lender’s unused Working Capital Commitment such that its Working Capital Commitment Exposure does not exceed its Working Capital Commitment after giving effect to such Working Capital Loan, from time to time during the period commencing on the Working Capital Loan Availability Date and, in each case, ending on the earliest to occur of the following dates (the “Working Capital Loan Termination Date”) (such period, the “Working Capital Loan Availability Period”):

  (i) the Final Maturity Date;

 (ii) the date of any cancellation or termination of all of the remaining Working Capital Commitments pursuant to Section 2.07 (Termination or Reduction of Commitments); and

(iii) the date the Working Capital Lenders terminate their Working Capital Commitments upon the occurrence and during the Continuance of a Working Capital Facility Event of Default.

 

5


(b) Notwithstanding anything to the contrary in Section 2.04(a) above, including the occurrence of the Working Capital Loan Availability Date, prior to the Project Completion Date, the outstanding aggregate amount of Working Capital Loans at any time shall be no greater than the Pre-Completion Working Capital Loan Sublimit.

(c) Subject to the conditions of Section 2.03 (Working Capital Loans), Section 7.01 (Conditions to Closing) (which incorporates by reference Section 4.1 (Condition to Closing Date and Initial Advance) of the Common Terms Agreement) and Section 7.02 (Conditions to Each Working Capital Advance) of this Agreement (which incorporates by reference Section 4.3 (Condition to Each Advance under the Working Capital Facility) of the Common Terms Agreement), and this Section 2.04 (Working Capital Loan Availability), the Borrower shall be entitled to draw all or a portion of the unused Working Capital Commitments before or on the final date of the Working Capital Availability Period for the purposes set forth in Section 12.1 (Use of Proceeds) of the Common Terms Agreement and Section 2.10(b) (Use of Proceeds).

Section 2.05 Procedures for Requesting Advances.

(a) From time to time, but no more frequently than twice per calendar month (except as required for the payment of interest or Commitment Fees during the Term Loan Availability Period, and for any draw of remaining Term Loan Commitments on the last day of the Term Loan Availability Period), subject to the limitations set forth in Sections 2.01 (Term Loans), and 2.02 (Term Loan Availability) above and Sections 2.2 (Sequence of Advances of Senior Debt) and 2.4 (Pro Rata Advances) of the Common Terms Agreement, the Borrower may request a Term Loan Advance by delivering to the Credit Facility Agent a properly completed Disbursement Request in accordance with Section 2.3 (Disbursement Procedures) of the Common Terms Agreement and this Section 2.05 (Procedures for Requesting Advances).

(b) The aggregate amount of any proposed Term Loan Advance under this Agreement must be an amount that is no more than the available Term Loan Commitments and not less than $10,000,000 and an integral multiple of $1,000,000 (unless the available Term Loan Commitments are less than $10,000,000). Such Advances shall be made pro rata with respect to other Facility Agreements in accordance with the committed principal amounts under the Term Loan Commitment subject to and in accordance with Section 2.4 (Pro Rata Advances) of the Common Terms Agreement.

(c) From time to time, subject to the limitations set forth in Section 2.03 (Working Capital Loans) and Section 2.04 (Working Capital Loan Availability) above, the Borrower may request a Working Capital Advance by delivering to the Credit Facility Agent a properly completed Disbursement Request in accordance with this Section 2.05 (Procedures for Requesting Advances) and Section 2.3 (Disbursement Procedures) of the Common Terms Agreement. Working Capital Advances under this Agreement may be made concurrently with but shall not be required to be made pro rata with borrowings under any other Facility Agreements. For the avoidance of doubt, Working Capital Advances shall be required to be borrowed pro rata based on each Working Capital Lender’s Commitment Percentage.

 

6


(d) The amount of any proposed Working Capital Advance under this Agreement must be an amount that is no more than the unused Aggregate Working Capital Commitments and not less than $5,000,000 and an integral multiple of $1,000,000 (unless the unused Aggregate Working Capital Commitments are less than $5,000,000).

(e) The Credit Facility Agent shall promptly advise each Lender that has a Commitment that is to fund any portion of the Term Loan Advance or Working Capital Advance, as applicable, of any Disbursement Request delivered pursuant to this Section 2.05 (Procedures for Requesting Advances), together with each such Lender’s Commitment Percentage of the requested Advance.

(f) Any Disbursement Request delivered pursuant to clause (a) or (c) above shall be delivered by the Borrower to the Credit Facility Agent by 1:00 p.m. on or before the third (3rd) Business Day prior to the requested Advance Date for the Advance of any LIBOR Loans and 1:00 p.m. on or before the Business Day prior to the requested Advance Date for the Advance of any Base Rate Loans; provided that the notice periods set forth in this clause (f) shall not apply with respect to the Disbursement Request for the Initial Advance, which Disbursement Request may be delivered no later than 11:00 a.m. on the Business Day before the requested Advance Date.

(g) Each Disbursement Request delivered pursuant to this Section 2.05 (Procedures for Requesting Advances) shall be substantially in the form of Schedule B-1 to the Common Terms Agreement (Disbursement Request Form (Term Loans)) or Schedule B-2 (Disbursement Request Form (Working Capital Loans)). Each such Disbursement Request shall be irrevocable and shall refer to this Agreement and specify:

  (i) whether the requested Advance is of Working Capital Loans or Term Loans and, to the extent the requested Advance would constitute Term Loans, whether the requested Advance is to be funded from the Base Term Loan Commitment and/or the Contingency Reserve Term Loan Commitment;

 (ii) the requested Advance Date (which shall be a Business Day);

(iii) the amount of such requested Advance (including, where applicable, the amount to be funded from the Base Term Loan Commitment and/or the Contingency Reserve Term Loan Commitment);

(iv) whether the requested Advance is of LIBOR Loans or Base Rate Loans;

 (v) in the case of a requested Advance of LIBOR Loans, the Borrower’s election with respect to the duration of the initial Interest Period applicable to such LIBOR Loans, which Interest Period shall be one (1), two (2), three (3), six (6), nine (9) or twelve (12) months in length;

(vi) if the requested Advance is (A) of a Term Loan, that each of the conditions precedent to such Term Loan Advance has been satisfied or waived in accordance with Section 7.01 (Conditions to Closing) or Section 7.02 (Conditions to

 

7


Each Term Loan Advance), as applicable, or (B) of a Working Capital Loan, that each of the conditions precedent to such Working Capital Advance has been satisfied or waived in accordance with Section 7.01 (Conditions to Closing) or Section 7.03 (Conditions to Each Working Capital Advance);

 (vii) if such Disbursement Request is being made pursuant to Section 2.10(a) or Section 2.10(b) (Use of Proceeds); and

(viii) the wire information of the account to which the proceeds of such Advance are to be deposited.

The currency specified in a Disbursement Request must be US Dollars.

(h) If no election as to whether the requested Advance is of LIBOR Loans or Base Rate Loans, then the requested Advance shall be of LIBOR Loans; provided that, if the applicable Disbursement Request is delivered to the Credit Facility Agent later than 1:00 p.m. on the third (3rd) Business Day prior to the proposed Advance Date, the requested Advance shall be of Base Rate Loans. If no initial Interest Period is specified with respect to any requested LIBOR Loans, then the requested Advance shall be made as a LIBOR Loan with an initial Interest Period of one (1) month.

Section 2.06 Funding. (a) Subject to clause (c) below, on the proposed Advance Date of each Advance, each Lender shall make a Term Loan or a Working Capital Loan, as applicable, in the amount of its Commitment Percentage of such Advance by wire transfer of immediately available funds to the Credit Facility Agent, not later than 1:00 p.m. and the Credit Facility Agent shall transfer and deposit the amounts (i) constituting proceeds of Term Loans so received as set forth in Section 2.01(c) or (d) (Term Loans), as applicable, for application in accordance with Section 4.5(a) (Deposits and Withdrawals – Disbursements of Senior Debt), Section 4.5(c) (Deposits and Withdrawals – Construction Account) and Section 4.5(k) (Deposits and Withdrawals – Contingency Reserve Account) of the Common Security and Account Agreement, as applicable and (ii) constituting proceeds of Working Capital Loans so received as set forth in Section 2.03(c) (Working Capital Loans); provided that, if an Advance does not occur on the proposed Advance Date because any condition precedent to such requested Advance herein specified has not been met, the Credit Facility Agent shall return the amounts so received to each applicable Lender without interest as soon as possible.

(b) Subject to Section 5.04 (Obligation to Mitigate), each Lender may (without relieving the Borrower of its obligation to repay a Loan in accordance with the terms of this Agreement and the Notes), at its option, fulfill its Commitments with respect to any such Loan by causing any domestic or foreign branch or Affiliate of such Lender to make such Loan.

(c) Unless the Credit Facility Agent has been notified in writing by any Lender prior to a proposed Advance Date that such Lender will not make available to the Credit Facility Agent its portion of the Advance proposed to be made on such date, the Credit Facility Agent may assume that such Lender has made such amounts available to the Credit Facility Agent on such date and the Credit Facility Agent in its sole discretion may, in reliance upon such

 

8


assumption, make available to the Borrower a corresponding amount. If such corresponding amount is not in fact made available to the Credit Facility Agent by such Lender and the Credit Facility Agent has made such amount available to the Borrower the Credit Facility Agent shall be entitled to recover on demand from such Lender such corresponding amount plus interest on such corresponding amount in respect of each day from the date such corresponding amount was made available by the Credit Facility Agent to the Borrower to the date such corresponding amount is recovered by the Credit Facility Agent at an interest rate per annum equal to the Federal Funds Effective Rate. If such Lender pays such corresponding amount (together with such interest), then such corresponding amount so paid shall constitute such Lender’s Term Loan or Working Capital Loan, as applicable, included in such Advance. If such Lender does not pay such corresponding amount forthwith upon the Credit Facility Agent’s demand, the Credit Facility Agent shall promptly notify the Borrower and the Borrower shall promptly repay such corresponding amount to the Credit Facility Agent plus interest on such corresponding amount in respect of each day from the date such corresponding amount was made available by the Credit Facility Agent to the Borrower to the date such corresponding amount is recovered by the Credit Facility Agent at an interest rate per annum equal to the Base Rate plus the Applicable Margin. If the Credit Facility Agent receives payment of the corresponding amount from each of the Borrower and such Lender, the Credit Facility Agent shall promptly remit to the Borrower such corresponding amount. If the Credit Facility Agent receives payment of interest on such corresponding amount from each of the Borrower and such Lender for an overlapping period, the Credit Facility Agent shall promptly remit to the Borrower the amount of such interest paid by the Borrower for such period. Nothing herein shall be deemed to relieve any Lender from its obligation to fulfill its Commitments hereunder and, for the avoidance of doubt, a Lender that fails to make its portion of any Advance on the due date for such payment hereunder shall be deemed in default of its obligations under Section 2.01 (Term Loans) or Section 2.03 (Working Capital Loans) above, as applicable. Any payment by the Borrower pursuant to this Section 2.06(c) (Funding) shall be without prejudice to any claim the Borrower may have against a Lender that shall have failed to make such payment to the Credit Facility Agent. The failure of any Lender to make available to the Credit Facility Agent its portion of the Advance shall not relieve any other Lender of its obligations, if any, hereunder to make available to the Credit Facility Agent its portion of the Advance on the date of such Advance, but no Lender shall be responsible for the failure of any other Lender to make available to the Credit Facility Agent such other Lender’s portion of the Advance on the date of any Advance. A notice of the Credit Facility Agent to any Lender or the Borrower with respect to any amounts owing under this Section 2.06(c) (Funding) shall be conclusive, absent manifest error.

(d) Each Lender shall maintain in accordance with its usual practice and form an account or accounts evidencing the Indebtedness of the Borrower to such Lender resulting from each Loan made by such Lender, including the amounts of principal and interest payable and paid to such Lender from time to time hereunder.

(e) The Credit Facility Agent shall maintain at one of the Credit Facility Agent’s offices (i) a copy of any Lender Assignment Agreement delivered to it pursuant to Section 11.04 (Assignments), and (ii) a register for the recordation of (A) the names and addresses of the Lenders and the Issuing Banks, (B) all the Commitments of, and principal amount of and interest on the Loans owing and paid to, each Lender pursuant to the terms hereof from time to time, (C)

 

9


the amount, beneficiary and termination date of all outstanding Letters of Credit, (D) the Issuing Bank Limit of each Issuing Bank and (E) amounts received by the Credit Facility Agent from the Borrower and whether such amounts constitute principal, interest, fees or other amounts and each Lender’s or Issuing Bank’s share thereof (the “Register”). The Register shall be available for inspection by the Borrower, any Issuing Bank and any Lender (with respect to such Issuing Bank’s Issuing Bank Limits, Fronting Limits and/or Non-Fronting Limits and such Lender’s Commitments and/or Loans, as applicable) at any reasonable time and from time to time upon reasonable prior notice.

(f) The entries made by the Credit Facility Agent in the Register or the accounts maintained by any Lender shall be conclusive and binding evidence, absent manifest error, of the existence and amounts of the obligations recorded therein; provided that the failure of any Lender or the Credit Facility Agent to maintain such Register or accounts or any error therein shall not in any manner affect the obligation of the Borrower to repay the Loans in accordance with the terms of this Agreement. In the event of any conflict between the accounts and records maintained by any Lender and the accounts and records of the Credit Facility Agent in respect of such matters, the accounts and records of the Credit Facility Agent shall control, in the absence of manifest error.

(g) In addition to such accounts or records described in clauses (d) and (e) of this Section 2.06 (Funding), the Loans made by each Lender may, upon the request of any Term Lender, be evidenced by a Term Loan Note or Term Loan Notes, in the case of Term Loans, or a Working Capital Loan Note or Working Capital Loan Notes, in the case of Working Capital Loans, in each case, duly executed on behalf of the Borrower and dated the date of any request therefor by a Lender. Each such Note shall have all blanks appropriately filled in, and shall be payable to such Lender and its registered assigns in a principal amount equal to the Term Loan(s) and Working Capital Loan(s) of such Lender; provided that each Lender may attach schedules to its respective Note(s) and endorse thereon the date, amount and maturity of its respective Loan(s).

Section 2.07 Termination or Reduction of Commitments. (a) (i) All unused Term Loan Commitments, if any, shall be automatically and permanently terminated (without premium or penalty) as of 5:00 p.m. on the last day of the Term Loan Availability Period that is a Business Day and (ii) all then-unused Working Capital Commitments, if any, shall be automatically and permanently terminated (without premium or penalty) as of 5:00 p.m. on the last day of the Working Capital Availability Period that is a Business Day.

(b) The Borrower may cancel or reduce permanently the whole or any part of the unutilized Term Loan Commitments and/or Working Capital Commitments (together with a corresponding ratable cancellation or reduction of the Issuing Bank Limits for each Issuing Bank by the amount by which the Issuing Bank Limits exceed the Aggregate Working Capital Commitments after giving effect to the cancellation or reduction of unutilized Working Capital Commitments), in either case, in accordance with Section 3.2 (Right of Repayment and Cancellation in Relation to a Single Facility Lender), Section 3.7 (Pro Rata Payment) and Section 3.8 (Reductions and Cancellations of Facility Commitments) of the Common Terms Agreement (provided that Section 3.8(c) thereof shall not apply to a reduction or cancellation of

 

10


Working Capital Commitments) and upon at least three (3) Business Days’ prior written notice to the Credit Facility Agent (with a copy to any applicable Issuing Bank) and certification by the Borrower to the Credit Facility Agent that the letter of credit capacity under the portion of the Working Capital Commitments to be cancelled or reduced, after taking into account other funding sources irrevocably available to the Obligors, is not required to satisfy any express obligation of either Obligor to provide performance security; provided that, (x) the Borrower may not cancel or reduce any part of the Contingency Reserve Term Loan Commitments until the Project Completion Date and (y) in the event the Borrower cancels or reduces any part, but not all, of the Commitments prior to the Project Completion Date (other than in accordance with Section 6.3 (Replacement Senior Debt) of the Common Terms Agreement), the Borrower shall deliver to the Credit Facility Agent a certification (confirmed in writing by the Independent Engineer) that such cancellation or reduction will not result in the Obligors’ having an insufficient amount of committed or funded capital to fund (on the basis of all other available funds, including funds in the Construction Account and remaining Commitments) the remaining expenditures required to achieve the Project Completion Date by the Date Certain; provided, further, that, in accordance with Section 3.8 (Reductions and Cancellations of Facility Commitments) and Section 3.7(b)(i) (Pro Rata Payments) of the Common Terms Agreement and Section 2.3(a) (Payments and Prepayments – Pro Rata Payment of Senior Debt Obligations) of the Common Security and Account Agreement (i) any such cancellation of Working Capital Commitments and Issuing Bank Limits may be made without pro rata cancellation of Facility Commitments under any other Facility Agreements then in effect and (ii) the Working Capital Lenders shall not be entitled to pro rata cancellation in the case of a cancellation of Facility Commitments under any other Facility Agreements. Where such cancellation or reduction is to be made pro rata, the applicable Commitments and Issuing Bank Limits (if such cancellation or reduction is with respect to Working Capital Commitments) shall be automatically and permanently reduced pro rata among all Lenders and Issuing Banks holding such Commitments and Issuing Bank Limits in accordance with their respective Commitment Percentages. Any such partial cancellation or reduction (A) of Term Loan Commitments pursuant to this Section 2.07(b) shall be in a minimum amount of $5,000,000 and (B) of Working Capital Commitments shall be in an amount of $5,000,000 or an integral multiple of $5,000,000 in excess thereof (or, in each case, if less the remaining amount of such Commitment). From the effective date of any such reduction or cancellation, the Commitment Fees shall be computed on the undrawn portion of the applicable Commitments as so reduced or cancelled.

(c) On the date of incurrence of any Replacement Senior Debt in accordance with Section 6.3 (Replacement Senior Debt) of the Common Terms Agreement incurred to replace all or any part of the Term Loan, the Term Loan Commitments of the Term Lenders shall be reduced in accordance with Section 3.8(a) (Reductions and Cancellations of Facility Commitments) of the Common Terms Agreement; provided that the Borrower shall be deemed to have repaid Term Loans and cancelled Facility Commitments on a pro rata basis by applying the proceeds of such Replacement Senior Debt first to repay any outstanding Term Loans in accordance with Section 4.16(c) (Pro Rata Treatment), and, to the extent any Replacement Senior Debt proceeds remain, secondly to cancel Term Loan Commitments that subsequently remain available to be drawn on a pro rata basis. On the date of incurrence of any Replacement Senior Debt in accordance with Section 6.3 (Replacement Senior Debt) of the Common Terms Agreement, no pro rata repayment of Working Capital Loans or cancellations of Working

 

11


Capital Commitments shall be required to be made by the Obligors unless such Replacement Senior Debt has been incurred to replace all or any part of the Working Capital Loans and/or Working Capital Commitments.

(d) The Borrower shall have the right to replace any Non-Consenting Lender on a non-pro rata basis, pursuant to Section 5.04(b) (Obligation to Mitigate).

(e) All unused Commitments, if any, shall be terminated upon the occurrence and Continuance of a Loan Facility Event of Default if required pursuant to Section 9.02 (Acceleration Upon Bankruptcy) or Section 9.03 (Action Upon Event of Default) in accordance with the terms thereof.

Section 2.08 [Reserved].

Section 2.09 Incremental Commitments.

(a) The Borrower may from time to time, by written notice to the Credit Facility Agent (a “Working Capital Commitment Increase Notice”), request increases in the Working Capital Commitments (together with any applicable corresponding increases in the Issuing Bank Limits) of the relevant Working Capital Lender, Issuing Bank or by any other Person that is an Eligible Assignee or satisfies the rating requirement set forth in the definition of “Issuing Bank”, as applicable (each, a “Working Capital Commitment Increase”), up to an aggregate principal amount not to exceed the maximum amount of Working Capital Debt permitted pursuant to Section 6.2(a) (Working Capital Debt) of the Common Terms Agreement.

(b) The Working Capital Commitment Increase Notice shall specify (i) the date on which the Borrower proposes that such Working Capital Commitment Increase shall be effective, which shall be a date not less than thirty (30) days after the date on which such notice is delivered to the Credit Facility Agent, (ii) the amounts of the Working Capital Commitment Increase (including any proposed increase in Non-Fronting Limit or Fronting Limit of an Issuing Bank) and (iii) the identity of each Working Capital Lender, Issuing Bank or other Person that is an Eligible Assignee or satisfies the rating requirement set forth in the definition of “Issuing Bank”, as applicable (each, an “Incremental Lender/Issuing Bank”) to whom the Borrower proposes any portion of the Working Capital Commitment Increase be allocated and the amounts of such allocations; provided that, any Working Capital Lender, Issuing Bank or other Person approached to provide all or a portion of the Working Capital Commitment Increase may elect or decline, in its sole and absolute discretion, to participate.

(c) Each Working Capital Commitment Increase shall become Working Capital Commitments, Issuing Bank Limits, Non-Fronting Limits or Fronting Limits (as applicable) (or, in the case of an increase in the commitment of an existing Working Capital Lender or Issuing Bank, an increase in such Working Capital Lender’s or Issuing Bank’s applicable Working Capital Commitment, Issuing Bank Limit, Non-Fronting Limit or Fronting Limit (as applicable)) under this Agreement pursuant to an amendment (such amendment, an “Incremental Amendment”) to this Agreement executed by the Borrower, the Credit Facility Agent and each Incremental Lender/Issuing Bank (with the consent of no other Working Capital Lender being

 

12


required) which provides solely for (i) the increase in the applicable Working Capital Commitments, Issuing Bank Limits, Non-Fronting Limits or Fronting Limits (as applicable) proposed in the applicable Working Capital Commitment Increase Notice and consented to by the applicable Incremental Lender/Issuing Bank, (ii) amendments required to reflect the relative unfunded Commitments of the Incremental Lenders/Issuing Banks and (iii) the joinder of each Incremental Lender/Issuing Bank that is not already an existing Working Capital Lender or Issuing Bank party to this Agreement. The effectiveness of any Incremental Amendment shall be subject solely to the conditions that (A) no Loan Facility Event of Default or Unmatured Loan Facility Event of Default shall exist on such date of effectiveness before or after giving effect to such Working Capital Commitment Increase, (B) each Incremental Lender that is not already a Working Capital Lender shall be entitled to receipt of any required reliance letters in respect of the legal opinions provided to the Credit Facility Agent pursuant to Section 4.1(f) (Conditions to Closing Date and Initial Advance – Opinions from Counsel) of the Common Terms Agreement, (C) since the time of the financial statements most recently provided pursuant to Section 10.1(a) (Accounting, Financial and Other Information) of the Common Terms Agreement no developments have occurred which, individually or in the aggregate have resulted in or could reasonably be expected to result in a Material Adverse Effect, (D) each Incremental Lender/Issuing Bank who is not already a Working Capital Lender or Issuing Bank is reasonably acceptable to the Credit Facility Agent and each Issuing Bank and (E) the Intercreditor Agent has received, at least three (3) Business Days before the effectiveness of such Incremental Amendment, a certificate from the Borrower that (1) identifies each holder of Working Capital Commitments (after giving effect to the applicable Working Capital Commitment Increase) and (2) attaches a copy of the proposed Incremental Amendment.

Section 2.10 Use of Proceeds.

(a) The Borrower shall be permitted to use the proceeds of:

 (i) Term Loans funded from the Base Term Loan Commitment solely: (A) to pay Project Costs, including the payment of Permitted Completion Costs and funding the Senior Facilities Debt Service Reserve Account and the Contingency Reserve Account, (B) to make Authorized Investments, (C) to reimburse Drawstop Equity Contributions previously made in accordance with Section 11.2(c) of the Common Terms Agreement (Certain Restricted Payments) and Section 4.5(c) (Deposits and Withdrawals – Construction Account) of the Common Security and Account Agreement, (D) to make the Initial Advance into the Credit Agreement Reserve Account pursuant to Section 4.5(h) (Deposits and Withdrawals – Credit Agreement Reserve Account) of the Common Security and Account Agreement and (E) to pay transaction costs, fees and expenses in connection with the closing of the Senior Debt and the Development; and

(ii) Term Loans funded from the Contingency Reserve Term Loan Commitment solely (A) prior to the Project Completion Date, to fund the Contingency Reserve Account for application to pay Project Costs, to the extent the aggregate amount of funds then on deposit in (x) the Pre-Completion Revenue Account (which funds have been transferred to the Contingency Reserve Account in accordance with Section 4.5(b)(ii)(C) of the Common Security and Account Agreement (Deposits and

 

13


Withdrawals – Pre-Completion Revenues Account)) and (y) without duplication of the amounts described in the foregoing clause (x), the Contingency Reserve Account are insufficient to fund such Project Costs and (B) on the Project Completion Date, to fund the withdrawals and transfers contemplated by Section 14.2 (Project Completion Date Waterfall) of the Common Terms Agreement.

(b) The Borrower shall be permitted to use the Letters of Credit and the proceeds of Working Capital Loans solely for working capital purposes of the Obligors, including to satisfy the Obligors’ credit support obligations under the Material Project Agreements; provided, that prior to the Project Completion Date, the Borrower shall be permitted to use the proceeds of Working Capital Loans solely (i) for purchases of natural gas required by the Borrower for testing or operations of the Project Facilities and (ii) to the extent the Borrower has entered into one or more agreements, in each case with a third party who is not an Affiliate of the Borrower, for the purchase and sale of LNG that fully mitigates any commodity price risk resulting from the purchase of natural gas contemplated by the immediately foregoing clause (i) such that the Borrower has contracted to achieve a positive margin from the sale of LNG associated with such purchased gas volumes, as certified by an Authorized Officer (who is a financial officer) of the Borrower; provided further, that the Borrower shall not borrow amounts under the Working Capital Facility or use the proceeds of Working Capital Loans to meet any requirement under any other Senior Debt Instrument governing the Working Capital Debt that the Borrower reduce the principal amount relating to any revolving loans under such other Senior Debt Instrument to $0 for a period of at least five (5) consecutive Business Days at least once per calendar year (it being acknowledged and agreed that the foregoing shall not limit the utilization by the Borrower of other Indebtedness that is permitted to be incurred pursuant to Section 12.14 (Limitation on Indebtedness) of the Common Terms Agreement for such purposes to the extent the terms and conditions of such Indebtedness permit such utilization).

ARTICLE III

LETTERS OF CREDIT

Section 3.01 Letters of Credit.

(a) Subject to the terms and conditions set forth herein and, as applicable, the terms and conditions set forth in the Common Terms Agreement, during the Working Capital Availability Period, the Borrower may (but is not required to), deliver to (1) the Credit Facility Agent (which shall promptly distribute copies thereof to the Working Capital Lenders), (2) the Issuing Bank designated by the Borrower (with the consent of such Issuing Bank in its sole discretion) with respect to Fronted Letters of Credit and (3) each Issuing Bank with a Non-Fronting Limit with respect to Non-Fronted Letters of Credit, a letter of credit request substantially in the form of Schedule B-3 to the Common Terms Agreement (Issuance Request Form (Letters of Credit) or such other form as requested by the Borrower and reasonably acceptable to the applicable Issuing Bank (a “Request for Issuance”) for the issuance, extension, modification or amendment of a Letter of Credit from time to time during the Working Capital Availability Period. Each Request for Issuance shall include (i) the date (which shall be a Business Day, but in no event later than the date that occurs five (5) Business Days prior to the Final Maturity Date) of issuance of such Letter of Credit (or the date of effectiveness of such

 

14


extension, modification or amendment) and the stated expiry date thereof (which will be consistent with Section 3.01(d)), (ii) the proposed stated amount of such Letter of Credit, (iii) the intended beneficiary of such Letter of Credit, (iv) a description of the intended use of such Letter of Credit and (v) whether such Letter of Credit is to be a Fronted Letter of Credit or a Non-Fronted Letter of Credit. Each Request for Issuance shall be irrevocable unless modified or rescinded by the Borrower not less than three (3) Business Days prior to the proposed date of issuance (or effectiveness) specified therein.

(b) The Borrower may request Letters of Credit up to the lesser of (i) an aggregate stated amount for all requested and issued Letters of Credit of the aggregate of the Issuing Bank Limits of all Issuing Banks and (ii) the Aggregate Working Capital Commitments; provided, in each case, that no Issuing Bank shall be required to issue any Letter of Credit or any amendment to increase the face or stated amount of any Letter of Credit if, after such issuance or amendment, (A) the aggregate Working Capital Commitment Exposure for all Working Capital Lenders shall exceed the Aggregate Working Capital Commitments, (B) the LC Exposure of such Issuing Bank with a Fronting Limit shall exceed its Fronting Limit, (C) the LC Exposure of such Issuing Bank with a Non-Fronting Limit shall exceed its Non-Fronting Limit, (D) the LC Exposure of such Issuing Bank shall exceed its Issuing Bank Limit or (D) the Working Capital Commitment Exposure of such Issuing Bank shall exceed its Working Capital Commitment in its capacity as a Working Capital Lender. For the avoidance of doubt, subject to compliance with the foregoing requirements and Sections 3.01(a) and 3.01(f), the Borrower may request Fronted Letters of Credit from an Issuing Bank with a Fronting Limit up to the Issuing Bank’s full Fronting Limit.

(c) Promptly after its receipt of a Request for Issuance, the Issuing Bank will confirm with the Credit Facility Agent (in writing) that the Credit Facility Agent has received a copy of such Request for Issuance from the Borrower and, if not, the Issuing Bank will provide the Credit Facility Agent with a copy thereof. Unless the Issuing Bank has received notice (in writing) from the Credit Facility Agent (including at the request of any Working Capital Lender) no later than three (3) Business Days prior to the proposed date of issuance (or effectiveness) (i) directing the Issuing Bank not to issue (or extend, amend or modify) such Letter of Credit as a result of the limitations set forth in Section 3.01(b), or (ii) that one or more of the applicable conditions precedent in Section 7.03 (Conditions to Each Working Capital Advance) is not then satisfied or waived, then (A) the applicable Issuing Bank shall issue (or extend, modify or amend) each Letter of Credit not later than 1:00 p.m. on the later of (1) the proposed date of issuance (or effectiveness) specified in such Request for Issuance and (2) three (3) Business Days after the receipt of the Request for Issuance (taking into account that any Request for Issuance received after 1:00 p.m. on any Business Day will be deemed received on the next Business Day), and (B) such issuance (or effectiveness) shall be subject to the terms and conditions hereof, including fulfillment of the applicable conditions precedent and the other requirements set forth herein (including Sections 3.01(a) and 3.01(f)). An Issuing Bank that issues (or extends, amends or modifies) a requested Letter of Credit pursuant to this Section 3.01 shall issue (or extend, amend or modify) such Letter of Credit to the Borrower or directly to the intended beneficiary and shall provide notice and a copy thereof to the Intercreditor Agent and the Credit Facility Agent, which, in the case of a Fronted Letter of Credit, shall promptly furnish copies thereof to the Working Capital Lenders, and to the extent that such Letter of Credit was issued directly to the intended beneficiary, such Issuing Bank shall provide notice and a copy thereof to the Borrower.

 

15


(d) Each Letter of Credit shall expire no later than the earlier of (i) one year from the date of issuance of such Letter of Credit and (ii) five (5) Business Days prior to the Working Capital Loan Termination Date. Each Letter of Credit may, if requested by the Borrower, provide that it will be automatically renewed or extended for a stated period of time at the end of its then-scheduled expiration date and each successive expiration date (but in any event shall not be extended for longer than one year from the date of effectiveness of each such extension or beyond five (5) Business Days prior to the Working Capital Loan Termination Date) unless the Issuing Bank that issued the Letter of Credit notifies the beneficiary thereof no later than thirty (30) days prior to such expiration date that such Issuing Bank elects not to renew or extend such Letter of Credit. In no event shall the Working Capital Lenders have any obligation to pay any amount to (or for the account of) any Issuing Bank or any other Person, in respect of a drawing under a Letter of Credit that occurs after the Final Maturity Date.

(e) Notwithstanding anything in this Agreement to the contrary, no Issuing Bank will have any obligation to issue or renew, or extend the expiry date of, any Letter of Credit if (i) any judgment, order, or decree of any Governmental Authority or arbitrator shall by its terms purport to enjoin or restrain such Issuing Bank from issuing or renewing or extending the expiry date of such Letter of Credit or (ii) any Government Rule or any directive (whether or not having the force of law) from any Governmental Authority with jurisdiction over such Issuing Bank shall prohibit, or direct that such Issuing Bank refrain from, the issuance of new letters of credit or the renewal or extension of the expiry date of issued letters of credit generally or the issuance, renewal or extension of the expiry date of a Letter of Credit specifically or shall impose upon such Issuing Bank with respect to such Letter of Credit any restriction, reserve, or capital requirement, or shall impose upon such Issuing Bank any loss, cost, or expense. Each Issuing Bank shall provide the Borrower with prompt notice of the occurrence of any event described in this Section 3.01(e) not later than two (2) Business Days after obtaining knowledge of the occurrence of any such event.

(f) The Borrower may request that a Letter of Credit be Fronted Letter of Credit or a Non-Fronted Letter of Credit; provided that, (i) the Borrower may only request Fronted Letters of Credit from an Issuing Bank that is specified in this Agreement as having a Fronting Limit and who has consented to issue such Fronted Letter(s) of Credit in accordance with Section 3.01(a), and (ii) if the Borrower wishes to request Non-Fronted Letters of Credit, the Borrower shall determine the specific aggregate amount to be covered by such Letters of Credit to be provided to a specific beneficiary (the “Non-Fronted LC Amount”), and it shall make requests for Non-Fronted Letters of Credit simultaneously to all the Issuing Banks under this Agreement such that the aggregate stated amount of all such Non-Fronted Letters of Credit issued to such beneficiary is equal to the Non-Fronted LC Amount and the stated amount of the Non-Fronted Letter of Credit of each individual Issuing Bank is equal to its Commitment Percentage of the Non-Fronted LC Amount. No Working Capital Lender is required to participate in the extension of credit resulting from the issuance (or extension, modification or amendment) of a Non-Fronted Letter of Credit issued by an Issuing Bank other than itself. Each Working Capital Lender severally agrees with each Issuing Bank to participate in an amount equal to its

 

16


Commitment Percentage in the extension of credit resulting from the issuance (or extension, modification or amendment) of a Fronted Letter of Credit by such Issuing Bank and each drawing of the LC Available Amounts thereunder, in the manner and the amount provided in Section 3.02 (Reimbursement to Issuing Banks), and the issuance of such Fronted Letter of Credit shall be deemed to be a confirmation by the Issuing Bank and each Working Capital Lender of such participation in such amount; provided that, no Working Capital Lender shall be required to participate in a Fronted Letter of Credit to the extent such Working Capital Lender’s Working Capital Commitment Exposure would exceed its Working Capital Commitment as a result of such participation.

(g) In addition to the date of issuance, stated expiry date, stated amount, beneficiary, intended use and request for a Fronted Letter of Credit or Non-Fronted Letter of Credit specified in the applicable Request for Issuance, each Letter of Credit shall provide (unless the Borrower specifies otherwise in such Request for Issuance) for:

  (i) payment in immediately available funds in US Dollars on a Business Day;

 (ii) multiple drawings and partial drawings;

(iii) applicability of the International Standby Practices 1998, International Chamber of Commerce Publication No. 590 (1998) (“ISP98”), Uniform Customs and Practice for Documentary Credits, International Chamber of Commerce Publication No. 600 (2007) (“UCP 600”), or such other rules as the Borrower and the applicable Issuing Bank shall agree, and shall, as to matters not governed by ISP98, UCP 600 or such other rules, be governed and construed in accordance with the laws of the State of New York and applicable U.S. federal law;

(iv) a drawing by the beneficiary of the full available amount thereof if either (A) the Issuing Bank that issued the Letter of Credit ceases to satisfy the minimum credit ratings for an Issuing Bank hereunder (as set forth in the definition of “Issuing Bank” in Exhibit A (Definitions)) and such Letter of Credit has not been replaced by an Issuing Bank satisfying such minimum credit ratings within thirty (30) days or such shorter number of days as required under the document, if any, with respect to which such Letter of Credit is issued; provided that, the right to draw under this clause (A) shall only be included in the applicable Letter of Credit to the extent required under such document with respect to which such Letter of Credit is issued or (B) the Issuing Bank that issued the Letter of Credit notifies the Borrower (which shall promptly notify the beneficiary) no later than 60 days prior to the then-scheduled expiration date that such Issuing Bank elects not to renew or extend such Letter of Credit; and

 (v) in the case of a Non-Fronted Letter of Credit, the beneficiary will be required to certify that it is making a pro rata draw with all other Letters of Credit issued in favor of such beneficiary in respect of a Non-Fronted LC Amount based on the percentage of such Non-Fronted Letter of Credit to Non-Fronted LC Amount as notified to the beneficiary by the Borrower.

 

17


Section 3.02 Reimbursement to Issuing Banks.

(a) An Issuing Bank shall give the Credit Facility Agent, the Collateral Agent, the Borrower and each of the Working Capital Lenders prompt notice of any payment made by such Issuing Bank in accordance with the terms of any Letter of Credit issued by such Issuing Bank (an “LC Payment Notice”) no later than 10:00 a.m. on the Business Day immediately succeeding the date of such payment by such Issuing Bank.

(b) Upon delivery to the Borrower of an LC Payment Notice on or before 10:00 a.m., New York City time, on the Business Day immediately succeeding the date of such payment by an Issuing Bank, the Borrower shall either (i) on or before 12:00 noon on such Business Day, reimburse such Issuing Bank for such payment (an “LC Reimbursement Payment”) by paying to the Credit Facility Agent, for the account of such Issuing Bank, an amount equal to the payment made by such Issuing Bank plus interest on such amount at a rate per annum equal to the Base Rate plus the Applicable Margin for Base Rate Loans (provided that, if an Issuing Bank delivers an LC Payment Notice to the Borrower after 10:00 a.m. New York City time on the Business Day immediately succeeding the date of payment by such Issuing Bank, the Borrower shall make the LC Reimbursement Payment on or before 12:00 noon New York City time on the next succeeding Business Day) or (ii) (x) provide written notice to such Issuing Bank and the Credit Facility Agent electing to have the reimbursement obligation converted into an LC Loan in accordance with Sections 3.02(c) and (f) or (y) not make the LC Reimbursement Payment as required under Section 3.02(b)(i) (Reimbursement to Issuing Banks), in which case, in the case of this clause (ii), such reimbursement obligation shall automatically convert to an LC Loan as of such time; provided, that no Loan Facility Event of Default shall have occurred and been Continuing as of the time of the applicable payment made under the Letter of Credit. An Issuing Bank’s failure to provide an LC Payment Notice shall not relieve the Borrower of its obligation to reimburse such Issuing Bank for any payment it makes under any Letter of Credit. In the case of any Non-Fronted Letters of Credit issued with respect to a specific Non-Fronted LC Amount, the Borrower may not elect to make an LC Reimbursement Payment and/or convert a reimbursement obligation into a LC Loan for some but not all the Issuing Banks providing Non-Fronted Letters of Credit with respect to such Non-Fronted LC Amount.

(c) If the Borrower fails to make the LC Reimbursement Payment as required under Section 3.02(b) (Reimbursement to Issuing Banks) or provides written notice to such Issuing Bank and the Credit Facility Agent electing to have the reimbursement obligation converted into an LC Loan, such reimbursement obligation shall automatically convert to an LC Loan; provided, that no Loan Facility Event of Default shall have occurred and been Continuing as of the time of the applicable payment made under the Letter of Credit. If such LC Loan relates to a Fronted Letter of Credit, the Credit Facility Agent shall promptly notify each of the Working Capital Lenders of the amount of its share of the payment made under such Fronted Letter of Credit, which shall be such Working Capital Lender’s Commitment Percentage of such amount paid by such Issuing Bank (the “Working Capital Lender Payment Notice”). Subject to Section 3.01(f) (Letters of Credit), each Working Capital Lender hereby severally agrees to pay the amount specified in the Working Capital Lender Payment Notice in immediately available funds to the Credit Facility Agent for the account of such Issuing Bank with respect to a Fronted Letter of Credit plus interest on such amount at a rate per annum equal to the Federal Funds Effective

 

18


Rate from the date of such payment by such Issuing Bank to the date of payment to such Issuing Bank by such Working Capital Lender. Each Working Capital Lender shall make such payment by not later than 4:00 p.m. New York City time on the date it received the Working Capital Lender Payment Notice (if such notice is received at or prior to 1:00 p.m. New York City time) and before 12:00 noon New York City time on the next succeeding Business Day following such receipt (if such notice is received after 1:00 p.m. New York City time). In the case of Fronted Letters of Credit, each Working Capital Lender shall severally indemnify and hold harmless such Issuing Bank from and against any and all losses, liabilities (including liabilities for penalties), actions, suits, judgments, demands, costs, and expenses (including reasonable attorneys’ fees and expenses) resulting from any failure on the part of such Working Capital Lender to provide, or from any delay in providing, the Credit Facility Agent for the account of such Issuing Bank with its Commitment Percentage of the amount paid under the Fronted Letter of Credit but no such Working Capital Lender shall be so liable for any such failure on the part of or caused by any other Working Capital Lender or the willful misconduct or gross negligence, as determined by a court of competent jurisdiction by a final and non-appealable order, of the Credit Facility Agent. Each Working Capital Lender’s obligation to make each such payment to the Credit Facility Agent for the account of the applicable Issuing Bank in the case of payments made in respect of a Fronted Letter of Credit shall be several and not joint and shall not be affected by (A) the occurrence or continuance of any Loan Facility Event of Default (except as set forth in Section 3.02(b) and this Section 3.02(c)), (B) the failure of any other Working Capital Lender to make any payment under this Section 3.02 (Reimbursement to Issuing Banks), or (C) the date of the drawing under the applicable Letter of Credit issued by the applicable Issuing Bank; provided that, such drawing occurs prior to the earlier of (i) the Final Maturity Date or (ii) the termination date of the applicable Fronted Letter of Credit. Each Working Capital Lender further agrees that each such payment shall be made without any offset, abatement, withholding or reduction whatsoever.

(d) The Credit Facility Agent shall pay to the applicable Issuing Bank in immediately available funds the amounts paid in respect of a Fronted Letter of Credit pursuant to Section 3.02(b) (Reimbursement to Issuing Banks) and Section 3.02(c) (Reimbursement to Issuing Banks) before the close of business on the day such payment is received; provided that, any amount received by the Credit Facility Agent that is due and owing to such Issuing Bank and remains unpaid to such Issuing Bank on the date of receipt shall be paid on the next succeeding Business Day with interest payable at the Federal Funds Effective Rate.

(e) For so long as any Working Capital Lender is a Defaulting Lender under clause (a) of the definition thereof, such Defaulting Lender’s participation in LC Exposure shall be reallocated in accordance with Section 4.18(b) (Defaulting Lenders).

(f) Each payment made by a Working Capital Lender under subsection (c) above shall constitute an LC Loan deemed made by such Working Capital Lender to the Borrower on the date of such payment by an Issuing Bank under a Fronted Letter of Credit issued by such Issuing Bank. All such payments by the Working Capital Lenders in respect of any one such payment by such Issuing Bank shall constitute a single LC Loan hereunder. Each payment made by an Issuing Bank in respect of a Non-Fronted Letter of Credit that is not reimbursed by the Borrower or that is converted into an LC Loan by notice from the Borrower pursuant to clause

 

19


(c) above shall constitute an LC Loan deemed made by such Issuing Bank in its capacity as a Working Capital Lender. LC Loans that are converted to LIBOR Loans in respect of Non-Fronted Letters of Credit with respect to a specific Non-Fronted LC Amount shall constitute a single LIBOR Loan for the purposes of Section 4.05(e) (Interest Rates) hereunder. Each LC Loan initially shall be a Base Rate Loan.

Section 3.03 Obligations Absolute. The payment obligations of each Working Capital Lender under Section 3.02(c) (Reimbursement to Issuing Banks) and of the Borrower under this Agreement in respect of any payment under any Letter of Credit and any LC Loan shall be unconditional and irrevocable (subject only to the Borrower’s and each Working Capital Lender’s right to bring suit against an Issuing Bank pursuant to Section 3.04 (Liability of the Issuing Banks and the Working Capital Lenders) following the reimbursement of such Issuing Bank for any such payment), and shall be paid strictly in accordance with the terms of this Agreement under all circumstances, including the following circumstances:

(a) any lack of validity or enforceability of any Finance Document or any other agreement or instrument relating thereto or to such Letter of Credit;

(b) any amendment or waiver of, or any consent to departure from, all or any of the Finance Documents;

(c) the existence of any claim, set-off, defense or other right which the Borrower may have at any time against any beneficiary, or any transferee, of such Letter of Credit (or any Persons for whom any such beneficiary or any such transferee may be acting), any Issuing Bank, or any other Person, whether in connection with this Agreement, the transactions contemplated herein or by such Letter of Credit, or any unrelated transaction;

(d) any statement or any other document presented under such Letter of Credit proving to be forged, fraudulent, invalid or insufficient in any respect or any statement therein being untrue or inaccurate in any respect;

(e) payment in good faith by an Issuing Bank under any Letter of Credit issued by such Issuing Bank against presentation of a draft or certificate which does not comply with the terms of such Letter of Credit; or

(f) any other circumstance or happening whatsoever, whether or not similar to any of the foregoing.

Section 3.04 Liability of the Issuing Banks and the Working Capital Lenders. The Borrower assumes all risks of the acts and omissions of any beneficiary or transferee of any Letter of Credit, and none of the Credit Facility Agent, the Issuing Banks, the Working Capital Lenders nor any of their respective Related Parties shall be liable or responsible for (a) the use that may be made of such Letter of Credit or any acts or omissions of any beneficiary or transferee thereof in connection therewith; (b) the validity, sufficiency or genuineness of documents, or of any endorsement thereon, even if such documents should prove to be in any or all respects invalid, insufficient, fraudulent or forged; (c) payment by the applicable Issuing Bank against presentation of documents that do not comply with the terms of such Letter of

 

20


Credit, including failure of any documents to bear any reference or adequate reference to such Letter of Credit; or (d) any other circumstances whatsoever in making or failing to make payment under such Letter of Credit; provided that, in each case, payment by the applicable Issuing Bank shall not have constituted gross negligence or willful misconduct as determined by a court of competent jurisdiction by a final and non-appealable order, in which event the Borrower and each Working Capital Lender shall have the right to bring suit against an Issuing Bank, and such Issuing Bank shall be liable to the Borrower and any Working Capital Lender, to the extent of any direct, as opposed to consequential, damages suffered by the Borrower or such Working Capital Lender caused by such Issuing Bank’s willful misconduct or gross negligence as determined by a court of competent jurisdiction by a final and non-appealable order, including such Issuing Bank’s willful failure to make timely payment under such Letter of Credit following the presentation to it by the beneficiary thereof of a draft and accompanying certificate(s) which strictly comply with the terms and conditions of such Letter of Credit.

Section 3.05 Resignation as an Issuing Bank. Any Issuing Bank may, upon no less than thirty (30) days’ prior written notice to the Borrower (with a copy to the Credit Facility Agent, to be distributed to each Working Capital Lender) resign as an Issuing Bank, effective upon the appointment of a successor Issuing Bank in accordance with this Section 3.05. In the event of any such resignation as an Issuing Bank, the Borrower shall be entitled to appoint a successor Issuing Bank hereunder from among the Working Capital Lenders (provided, that the Borrower may not so appoint any Working Capital Lender if, as a result of such appointment, such Working Capital Lender’s (i) Working Capital Commitment Exposure would exceed its Working Capital Commitment or (ii) LC Exposure would exceed its Issuing Bank Limit, Fronting Limit or Non-Fronting Limit, as applicable) who meet the requirements hereunder to be an Issuing Bank; provided, however, that no failure by the Borrower to appoint any such successor shall affect the resignation of any Issuing Bank. If any Working Capital Lender resigns as an Issuing Bank, it shall retain all the rights, powers, privileges and duties of Issuing Bank hereunder with respect to all Letters of Credit that it issued, including Letters of Credit outstanding as of the effective date of its resignation as an Issuing Bank and all LC Exposure with respect thereto (including the right to require the Working Capital Lenders to make LC Loans or fund participations in Letters of Credit). Upon the appointment of a successor Issuing Bank and such successor Issuing Bank’s acceptance, in writing, of the appointment and agreement to be bound by all of the terms and conditions contained in this Agreement and the other Finance Documents binding on it in such capacity, (a) such successor shall succeed to and become vested with all of the rights, powers, privileges and duties of the Issuing Bank as the case may be and the successor Issuing Bank shall issue letters of credit in substitution for the Letters of Credit, if any, outstanding at the time of such succession or make other arrangements satisfactory to the applicable resigning Issuing Bank to effectively assume the obligations of such Issuing Bank with respect to such Letters of Credit.

Section 3.06 Non-Fronted Letters of Credit. The Borrower agrees that in the event that it has provided any Non-Fronted Letter of Credit in respect a Non-Fronted LC Amount, it shall instruct the beneficiary thereof to draw on such Non-Fronted Letter of Credit pro rata among all Non-Fronted Letters of Credit issued in respect of such Non-Fronted LC Amount. In the event that the Borrower has funded the Senior Debt Service Reserve Account using Non-Fronted Letters of Credit from each Issuing Bank, the Collateral Agent hereby agrees (without the need

 

21


for any further action or instruction from any Senior Creditors) to draw on such Non-Fronted Letters of Credit only on a pro rata basis as notified by the Borrower to the Collateral Agent or, failing such notification, as provided to the Collateral Agent by the Credit Facility Agent on request.

Section 3.07 Reinstatement of Letters of Credit. The stated amount of each Letter of Credit shall be reduced by the amount of any payment made by the applicable Issuing Bank on a drawing thereunder. Once so reduced, the stated amount of such Letter of Credit may only be reinstated upon and to the extent of any reimbursement by the Borrower of such drawing or, if reimbursement of such drawing is made through LC Loans, upon and to the extent of payment by the Borrower of the LC Loans corresponding to such drawing, in each case, pursuant to Section 3.02 (Reimbursement to Issuing Banks). At least one (1) Business Day prior to the date of any such reinstatement of a Letter of Credit, the Borrower shall deliver to such Issuing Bank and the Credit Facility Agent a written request for reinstatement signed by an Authorized Officer of the Borrower and in form and substance satisfactory to such Issuing Bank. Upon the effectiveness of any such reinstatement, such Issuing Bank shall notify the Borrower, the Credit Facility Agent and the beneficiary of the reinstated Letter of Credit and shall indicate in such notice the new stated amount of such Letter of Credit.

ARTICLE IV

REPAYMENTS, PREPAYMENTS, INTEREST AND FEES

Section 4.01 Repayment of Term Loan Advances.

(a) The Borrower unconditionally and irrevocably promises to pay to the Credit Facility Agent for the ratable account of each Term Lender the aggregate outstanding principal amount of the Term Loans on each CTA Payment Date beginning on the First Repayment Date, in accordance with the Amortization Schedule. In addition, following the making of any prepayments pursuant to this Agreement or Section 3.1 (CTA Payment Dates) of the Common Terms Agreement, including in connection with the incurrence of Replacement Senior Debt, the Credit Facility Agent shall, of its own motion or as reasonably requested by the Borrower, generate and promptly provide to the Intercreditor Agent and the Borrower a revised Amortization Schedule (in respect of which it shall have consulted with the Borrower). In any of the instances described above, the revised Amortization Schedule shall be delivered prior to the next Quarterly Payment Date and prepared in a manner that is consistent with the principles used to prepare the original Amortization Schedule. Any failure by the Credit Facility Agent to provide a revised Amortization Schedule as required pursuant to this Section 4.01 (Repayment of Term Loan Advances) shall not affect the Borrower’s obligations to pay the Term Loans in accordance with this Agreement.

(b) The repayment of principal by the Borrower for the Term Loans shall commence on the earlier of (such earlier date, the “First Repayment Date”):

  (i) the first Quarterly Payment Date (or, if such date is not a Business Day, the Business Day immediately prior to such Quarterly Payment Date) occurring more than three calendar months following the Project Completion Date; and

 

22


 (ii) the Date Certain.

(c) Notwithstanding anything to the contrary set forth in Section 4.01(a) above, the final principal repayment installment on the Final Maturity Date shall in any event be in an amount equal to the aggregate principal amount of all Term Loans outstanding on such date.

Section 4.02 Repayment of LC Loans. The Borrower unconditionally and irrevocably promises to pay to the Credit Facility Agent for the ratable account of each Working Capital Lender the aggregate outstanding principal amount of each LC Loan no later than 5:00 p.m. on the Working Capital Loan Termination Date.

Section 4.03 Repayment of Working Capital Advances.

(a) The Borrower shall reduce the aggregate outstanding principal amount of all Working Capital Loans to zero Dollars ($0) for a period of five (5) consecutive Business Days at least once every calendar year; provided that, the Borrower will determine in its sole discretion when during any calendar year it elects to satisfy such requirement and the Credit Facility Agent shall have no duty to monitor compliance with this Section 4.03(a); provided further that the Borrower may not borrow amounts under any other Facility Agreement for Working Capital Debt in order to meet the requirement specified in this Section 4.03(a).

(b) Notwithstanding anything to the contrary set forth in Section 4.03(a), the Borrower unconditionally and irrevocably promises to pay to the Credit Facility Agent for the ratable account of each Working Capital Lender, on the Working Capital Loan Termination Date, an amount equal to the aggregate principal amount of all Working Capital Loans then-outstanding.

Section 4.04 Interest Payment Dates. (a) Interest accrued on each Loan shall be payable, without duplication, on the following dates (each, an “Interest Payment Date”):

  (i) with respect to any repayment or prepayment of principal on such Loan, on the date of each such repayment or prepayment;

 (ii) on the Final Maturity Date;

(iii) with respect to Working Capital Loans and LC Loans, the Working Capital Loan Termination Date;

(iv) with respect to LIBOR Loans, (A) on the last day of each applicable Interest Period; provided, that in the case of any Interest Period that has a duration of more than three months, the Interest Payment Date in respect of such LIBOR Loans shall also include each day that is three months (or an integral multiple thereof) after the first day of such Interest Period, and (B) if applicable, on any date on which such LIBOR Loan is converted to a Base Rate Loan; and

 

23


(v) with respect to Base Rate Loans, on the last Business Day of each calendar quarter or, if applicable, any date on which such Base Rate Loan is converted to a LIBOR Loan.

(b) Interest accrued on the Loans or other monetary Loan Obligations after the date such amount is due and payable (whether on the Final Maturity Date or any CTA Payment Date upon acceleration or otherwise) shall be payable upon demand.

(c) Interest hereunder shall be due and payable in accordance with the terms hereof before and after judgment, and before and after the occurrence of an event set forth in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement and (to the extent Section 9.01 (Events of Default) covers the events described in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement) Section 9.01 (Events of Default) of this Agreement.

Section 4.05 Interest Rates.

(a) Each LIBOR Loan shall accrue interest at a rate per annum during each Interest Period applicable thereto equal to the sum of the LIBOR for such Interest Period plus the Applicable Margin for such Loan.

(b) On or before 1:00 p.m. at least three (3) Business Days prior to the end of each Interest Period for each LIBOR Loan, the Borrower shall deliver to the Credit Facility Agent an Interest Period Notice setting forth the Borrower’s election with respect to the duration of the next Interest Period applicable to such LIBOR Loan, which Interest Period shall be one (1), two (2), three (3), or six (6) (or, if available to all applicable Lenders, nine (9) or twelve (12)) months in length; provided, that, (i) if any Loan Facility Declared Default has occurred and is Continuing, all LIBOR Loans shall convert into Base Rate Loans and (ii) if any Unmatured Loan Facility Event of Default has occurred and is Continuing at the end of the then-current Interest Periods, all LIBOR Loans shall convert into LIBOR Loans with an Interest Period of one month, in each case, at the end of the then-current Interest Periods (in which case the Credit Facility Agent shall so notify the Borrower and the Term Lenders). After such Loan Facility Declared Default or Unmatured Loan Facility Event of Default has ceased, the Borrower may convert each such Base Rate Loan or LIBOR Loan with an Interest Period of one month into a LIBOR Loan in accordance with this Agreement by delivering an Interest Period Notice in accordance with Section 4.06 (Conversion Options).

(c) If the Borrower fails to deliver an Interest Period Notice in accordance with Section 4.05(b) above with respect to any LIBOR Loan, such LIBOR Loan shall be made as, or converted into, a Base Rate Loan at the end of the then-current Interest Period.

(d) Each LIBOR Loan shall bear interest from (and including) the first day of the applicable Interest Period to (but excluding) the last day of such Interest Period (or the date such Loan is converted to a Base Rate Loan) at the interest rate determined as applicable to such LIBOR Loan.

 

24


(e) Notwithstanding anything to the contrary contained herein, the Borrower shall have, in the aggregate, no more than ten (10) separate LIBOR Loans outstanding at any one time.

(f) Each Base Rate Loan shall accrue interest at a rate per annum equal to the sum of the Base Rate plus the Applicable Margin for such Loan.

(g) All Base Rate Loans shall bear interest from and including the date such Loan is made (or the day on which LIBOR Loans are converted to Base Rate Loans in accordance with Section 4.05(c) (Interest Rates) or 4.06 (Conversion Options) or under Article V (LIBOR And Tax Provisions)) to (but excluding) the date such Loan or portion thereof is paid at the interest rate determined as applicable to such Base Rate Loan (or the date such Loan is converted to a LIBOR Loan).

Section 4.06 Conversion Options. The Borrower may elect from time to time to convert LIBOR Loans to Base Rate Loans or Base Rate Loans to LIBOR Loans (subject to Sections 4.05(e) (Interest Rates), 5.01 (LIBOR Lending Unlawful) and 5.02 (Inability to Determine LIBOR)), as the case may be, by delivering a completed Interest Period Notice to the Credit Facility Agent notifying the Credit Facility Agent of such election no later than 12:00 noon on the third (3rd) Business Day preceding the proposed conversion date (which notice, in the case of conversions to LIBOR Loans, shall specify the length of the initial Interest Period therefor); provided that (i) no Base Rate Loan may be converted into a LIBOR Loan when any Loan Facility Declared Default has occurred and is Continuing and (ii) no Base Rate Loan may be converted into a LIBOR Loan with an Interest Period greater than one month when any Unmatured Loan Facility Event of Default has occurred and is Continuing and, in each case, the Credit Facility Agent has determined not to permit such conversions. Upon receipt of any such notice the Credit Facility Agent shall promptly notify each relevant Lender thereof.

Section 4.07 Post-Maturity Interest Rates; Default Interest Rates. If all or a portion of the principal amount of any Loan is not paid when due (whether on the Final Maturity Date, by acceleration or otherwise, or in the case of LC Loans, the Working Capital Loan Termination Date or otherwise) or any Loan Obligation (other than principal on the Loans) is not paid or deposited when due (whether on the Final Maturity Date, by acceleration or otherwise), (i) all such overdue amounts of principal on the Loans shall bear interest at a rate per annum equal to the rate that would otherwise be applicable thereto plus the Default Rate and (ii) all such other defaulted amounts of Loan Obligations (other than principal on the Loans) shall bear interest at a rate per annum equal to the rate then applicable to Base Rate Loans plus the Default Rate, from the date of such non-payment until the amount then due is paid in full (after as well as before judgment).

Section 4.08 Interest Rate Determination. The Credit Facility Agent shall determine the interest rate applicable to the Loans and shall give prompt notice of such determination to the Borrower and the applicable Lenders. In each such case, the Credit Facility Agent’s determination of the applicable interest rate shall be conclusive, in the absence of manifest error.

 

25


Section 4.09 Computation of Interest and Fees.

(a) All computations of interest for Base Rate Loans when the Base Rate is determined by the Credit Facility Agent’s “prime rate” shall be made on the basis of a year of 365 or 366 days, as the case may be, and actual days elapsed. All computations of interest for LIBOR Loans, and for Base Rate Loans when the Base Rate is determined by LIBOR shall be made on the basis of a 360 day year and actual days elapsed. All computations of commissions or fees owed hereunder (other than Commitment Fees, Fronting Fees and LC Fees, which shall be computed in accordance with the provisions of Section 4.15 (Fees) below) shall be made on the basis of a year of 365 or 366 days, as the case may be, and actual days elapsed.

(b) Interest shall accrue on each Loan for the day on which the Loan is made, and shall not accrue on a Loan, or any portion thereof, for the day on which the Loan or such portion is paid; provided, that, any Loan that is repaid on the same day on which it is made shall bear interest for one day.

(c) Each computation by the Credit Facility Agent of interest or fees hereunder shall be conclusive and binding for all purposes, absent manifest error.

Section 4.10 Terms of All Prepayments. The Borrower shall make prepayments of Loans and all reductions and cancellations of Commitments in accordance with the terms of Article 3 (Repayment, Prepayment and Cancellation) of the Common Terms Agreement and subject to the following terms and the terms of Section 4.11 (Voluntary Prepayments) and Section 4.12 (Mandatory Prepayment):

(a) upon the prepayment of any Loans (whether a voluntary prepayment, a mandatory prepayment or a prepayment upon acceleration or otherwise), the Borrower shall satisfy all applicable provisions under this Agreement; and

(b) together with any prepayment of Loans, the Borrower shall pay to the Credit Facility Agent, for the account of the applicable Lenders which made any Loan being prepaid, the sum of the following amounts:

  (i) the principal of, and accrued but unpaid interest on, the Loans to be prepaid;

 (ii) any additional amounts required to be paid under Section 5.05 (Funding Losses), which payment shall be made within the time period after the applicable prepayment as is permitted under the Common Terms Agreement; and

(iii) any other Loan Obligations required to be paid to the respective Lenders in connection with any prepayment under the Finance Documents.

Section 4.11 Voluntary Prepayment.

(a) The Borrower may, in accordance with Section 3.5 (Voluntary Prepayments) of the Common Terms Agreement and on not less than three (3) Business Days’ prior written notice to the Credit Facility Agent, prepay in whole or in part amounts outstanding under the Credit Facility Agreement, without penalty or premium (other than any Breakage Costs incurred as set

 

26


forth in Section 5.05 (Funding Losses)); provided, that, each voluntary prepayment of Loans shall be in incremental multiples of $1,000,000. Such notice may be conditional and subject to revocation as set forth in Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement. If any such notice is revoked in accordance with Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement, the Borrower shall pay any Breakage Costs incurred by any Lender as a result of such notice and revocation, as set forth in Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement. Prepayments of Working Capital Loans shall not result in any reduction in Working Capital Commitments, except to the extent prepaid in accordance with Sections 4.12(b)(ii), (iii) and (iv) (Mandatory Prepayment).

(b) Except as set forth in Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement, after the Borrower has delivered a notice of voluntary prepayment in accordance with Section 4.11(a) above, the prepayment date specified in the notice shall be deemed the due date for the principal amount (and the interest thereon) to be paid thereunder and should the Borrower fail to pay any such principal amount and/or interest and/or prepayment premium (if any), in accordance with Section 3.6 (Prepayment Fees and Breakage Costs) of the Common Terms Agreement and Section 5.05 (Funding Losses) due on such date, the Borrower shall pay interest on such overdue amounts in accordance with Section 4.07 (Post-Maturity Interest Rates; Default Interest Rates).

(c) Pursuant to Section 3.7 (Pro Rata Payments) of the Common Terms Agreement and Section 2.3(a)(i)(B) (Payments and Prepayments) of the Common Security and Account Agreement (i) any voluntary prepayment of Working Capital Loans or LC Loans may be made without a voluntary pro rata prepayment of Senior Debt under any other Senior Debt Instrument and (ii) any voluntary prepayment of Senior Debt under any other Senior Debt Instrument may be made without a voluntary pro rata prepayment of Working Capital Loans or LC Loans.

Section 4.12 Mandatory Prepayment.

(a) The Borrower shall prepay, with three (3) Business Days’ prior written notice to the Credit Facility Agent, the Term Loans as and when required under Section 3.4 (Mandatory Prepayments) and Section 3.7 (Pro Rata Payments) of the Common Terms Agreement.

(b) The Borrower shall prepay, with three (3) Business Days’ prior written notice to the Credit Facility Agent, the Working Capital Loans or LC Loans in accordance with Section 3.4 (Mandatory Prepayments) and Section 3.7 (Pro Rata Payments) of the Common Terms Agreement solely in the following circumstances:

  (i) other than LC Loans incurred to fund a reimbursement obligation with respect to a drawing under a Letter of Credit, as needed to comply with Section 4.03(a) (Repayment of Working Capital Advances); provided that, for the avoidance of doubt, the Borrower shall not be required to cause any issued and outstanding Letters of Credit to be cancelled or returned;

 (ii) in accordance with Section 3.4(a)(iii) (Mandatory Prepayments – LNG SPA Prepayment Event) of the Common Terms Agreement;

 

27


(iii) in accordance with Section 3.4(a)(vi) (Mandatory Prepayments – Illegality) of the Common Terms Agreement as a result of the occurrence of an Illegality Event with respect to a Working Capital Lender; and

(iv) in accordance with Section 3.4(a)(x) (Mandatory Prepayments – Replacement Debt) of the Common Terms Agreement in the event and to the extent the additional debt triggering such prepayment has been incurred to replace such Working Capital Loans and/or LC Loans.

Working Capital Commitments shall be cancelled in the case of the mandatory prepayments set forth in clauses (ii) and (iv) above as provided in Sections 3.4(a)(iii) (Mandatory Prepayments – LNG SPA Prepayment Event) and 3.4(a)(x) (Mandatory Prepayment – Replacement Debt) of the Common Terms Agreement, respectively, and shall be suspended in the case of the mandatory prepayment set forth in clause (iii) above as provided in Section 3.4(a)(vi) (Mandatory Prepayments – Illegality) of the Common Terms Agreement.

(c) Application of Prepayments of Loans to Base Rate Loans and LIBOR Loans. Any prepayment of Loans of a Lender pursuant to this Section 4.12 (Mandatory Prepayments) shall be applied first to such Lender’s Base Rate Loans to the full extent thereof and second to such Lender’s LIBOR Loans.

Section 4.13 Time and Place of Payments.

(a) Except as provided in Section 3.02(b) (Reimbursement to Issuing Banks), the Borrower shall make each payment (including any payment of principal of or interest on any Loan or any Fees or other Loan Obligations) hereunder without set-off, deduction or counterclaim not later than 12:00 noon New York City time on the date when due in Dollars and, in immediately available funds, to the Credit Facility Agent at the account set forth in Schedule IV (Credit Facility Agent Account Details) or at such other office or account as may from time to time be specified by the Credit Facility Agent to the Borrower. Funds received after 1:00 p.m. New York City time may, at the Credit Facility Agent’s discretion, be deemed to have been received by the Credit Facility Agent on the next succeeding Business Day.

(b) The Credit Facility Agent shall promptly remit in immediately available funds to each Credit Facility Secured Party its share, if any, of any payments received by the Credit Facility Agent for the account of such Credit Facility Secured Party.

(c) Whenever any payment (including any payment of principal of or interest on any Term Loan or any Fees or other Loan obligations) hereunder shall become due, or otherwise would occur, on a day that is not a Business Day, such payment shall (except as otherwise required by the proviso to the definition of “Interest Period” with respect to LIBOR Loans and in the case of the Final Maturity Date, in which case the due date for payment shall be the immediately preceding Business Day) be made on the immediately succeeding Business Day, and such increase of time shall in such case be included in the computation of interest or Fees, if applicable.

 

28


Section 4.14 Advances and Payments Generally.

(a) Except as provided in Section 3.02(b) (Reimbursement to Issuing Banks), unless the Credit Facility Agent has received notice from the Borrower prior to the date on which any payment is due to the Credit Facility Agent for the account of the Lenders or any Issuing Bank hereunder that the Borrower will not make such payment, the Credit Facility Agent may assume that the Borrower has made such payment on such date in accordance with this Agreement and may, in reliance upon such assumption, distribute to the Lenders or the applicable Issuing Bank(s) the amount due. If the Borrower has not in fact made such payment, then each of the Lenders or the applicable Issuing Bank(s) severally agrees to repay to the Credit Facility Agent forthwith on demand the amount so distributed to such Lender in immediately available funds with interest thereon, for each day from (and including) the date such amount is distributed to it to (but excluding) the date of payment to the Credit Facility Agent, at the Federal Funds Effective Rate. A notice of the Credit Facility Agent to any Lender or Issuing Bank with respect to any amount owing under this Section 4.14 (Advances and Payments Generally) shall be conclusive, absent manifest error.

(b) Nothing herein shall be deemed to obligate any Lender or Issuing Bank to obtain funds for any Loan or Letter of Credit reimbursement obligation in any particular place or manner or to constitute a representation by any Lender or Issuing Bank that it has obtained or will obtain funds for any Loan in any particular place or manner.

Section 4.15 Fees.

(a) From and including the Closing Date until the end of the Term Loan Availability Period or with respect to any Term Lender, until the date on which such Term Lender’s Term Loan Commitments are terminated (solely to the extent of such terminated Term Loan Commitments), the Borrower agrees to pay to the Credit Facility Agent, for the account of the Term Lenders, on each CTA Payment Date beginning on the first CTA Payment Date that is also an Interest Payment Date, a commitment fee (a “Term Loan Commitment Fee”) at a rate per annum equal to 35% of the Applicable Margin applicable to LIBOR Loans on the average daily amount by which the Term Loan Commitments exceed the aggregate outstanding principal amount of the Term Loans during the relevant fiscal quarter (or portion thereof) then ended; provided that all Commitment Fees shall be payable in arrears and computed on the basis of the actual number of days elapsed in a year of 360 days, as prorated for any partial quarter, as applicable. Notwithstanding the foregoing, the Borrower will not be required to pay any Commitment Fee to any Term Lender with respect to any period in which such Term Lender was a Defaulting Lender.

(b) From and including the Closing Date until the Working Capital Loan Termination Date, the Borrower agrees to pay to the Credit Facility Agent, for the account of each Working Capital Lender a commitment fee (a “Working Capital Commitment Fee” and, together with the Term Loan Commitment Fee, the “Commitment Fees”) on the daily average amount of such Working Capital Lender’s unused Working Capital Commitment at a rate per annum equal to 35% of the Applicable Margin for LIBOR Loans from the date hereof until the Final Maturity Date, payable quarterly in arrears on the last Business Day of each fiscal quarter, commencing on the first such date to occur following the date hereof, and the Working Capital Loan Termination Date. Notwithstanding the foregoing, the Borrower will not be required to pay any

 

29


Working Capital Commitment Fee to any Working Capital Lender with respect to any period in which such Working Capital Lender was a Defaulting Lender.

(c) The Borrower agrees to pay to the Credit Facility Agent for the account of each Working Capital Lender a letter of credit fee (the “LC Fee”) on (i) the average daily aggregate amount of such Working Capital Lender’s Commitment Percentage of the LC Available Amount, if any, of all Fronted Letters of Credit and (ii) the average daily aggregate amount of the LC Available Amount, if any, of any Non-Fronted Letters of Credit issued by such Working Capital Lender in its capacity as an Issuing Bank, each at a rate per annum equal to the Applicable Margin for LIBOR Loans, payable quarterly in arrears on the last Business Day of each fiscal quarter, commencing on the first such date to occur following the date of issuance of any Letter of Credit hereunder, and on the Working Capital Loan Termination Date; provided, however, that upon the occurrence and during the continuance of a Loan Facility Event of Default, with respect to any outstanding Letters of Credit which are not cash collateralized pursuant to Section 9.05 (Application of Proceeds), such LC Fee shall be increased by 2.0% per annum.

(d) The Borrower agrees to pay to each Issuing Bank a letter of credit fronting fee (the “Fronting Fee”) in an amount equal to 0.20% per annum of the aggregate LC Available Amount of each Fronted Letter of Credit issued by such Issuing Bank, payable quarterly in arrears on the last Business Day of each fiscal quarter, commencing on the first such date to occur following the date of issuance of such Letter of Credit hereunder, and on the Working Capital Loan Termination Date.

(e) The Borrower agrees to pay or cause to be paid to the Credit Facility Agent for the account of the Lenders and the Credit Facility Agent, additional fees in the amounts and at the times from time to time agreed to by the Borrower and the Credit Facility Agent, including pursuant to each fee letter with an Initial Coordinating Lead Arranger, Coordinating Lead Arranger or Documentation Bank and any other fee letters entered into by the Borrower with any of the Lenders from time to time in respect of the Credit Facility Agreement.

(f) All Fees shall be paid on the dates due in immediately available funds. Once paid, none of the Fees shall be refundable under any circumstances.

(g) All Commitment Fees, Fronting Fees and LC Fees shall be computed on the basis of 360-day year, as prorated for any partial quarter, as applicable.

(h) The Borrower shall not be liable to pay any Lender or Issuing Bank any upfront fees, fronting fees or agent fees, nor shall it be liable to pay any other fees, costs, expenses or charges with respect to the transactions contemplated under this Agreement, other than as may be specifically stated in this Agreement, the Fee Letters or any other agreement in writing between such Lender or Issuing Bank and the Borrower.

Section 4.16 Pro Rata Treatment.

(a) The portion of any Type of Loan or Advance made shall be allocated by the Credit Facility Agent among the applicable Lenders such that, following each Loan or Advance,

 

30


the ratio of each Lender’s outstanding Commitments of such Type to the outstanding Aggregate Commitment of such Type is equal to each Lender’s respective Commitment Percentage of such Type.

(b) Except as otherwise provided in Section 5.01 (LIBOR Lending Unlawful), each reduction of Commitments of any Type, pursuant to Section 2.07 (Termination or Reduction of Commitments) or otherwise, shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with, and subject to the exceptions in, Section 2.07 (Termination or Reduction of Commitments) and Section 3.8 (Reductions and Cancellations of Facility Debt Commitments) of the Common Terms Agreement. Each reduction in Issuing Bank Limits shall be allocated by the Credit Facility Agent pro rata among the Issuing Banks.

(c) Except as otherwise required under Section 3.7 (Pro Rata Payment) of the Common Terms Agreement and Section 4.11 (Voluntary Prepayment), Section 4.12 (Mandatory Prepayment) or Article V (LIBOR And Tax Provisions), (i) each payment or prepayment of principal of a Type of Loans shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with the respective principal amounts of their outstanding Loans of such Type (other than Defaulting Lenders), (ii) each payment of interest on a Type of Loans shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with the respective interest amounts outstanding on their Loans of such Type (other than Defaulting Lenders) and (iii) each payment of the Commitment Fees shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with their respective Term Loan Commitments or Working Capital Commitments (other than Defaulting Lenders), as applicable.

Section 4.17 Sharing of Payments.

(a) If any Lender or Issuing Bank obtains any payment or other recovery (whether voluntary, involuntary, by application of setoff or otherwise) on account of any Type of Loan (other than pursuant to the terms of Article V (LIBOR And Tax Provisions) or Section 4.16 (Pro Rata Treatment)) in excess of its pro rata share of payments then or therewith obtained by all Lenders holding Loans of such Type, such Lender or Issuing Bank shall purchase from the other applicable Lenders (for cash at face value) such participations in Loans of such Type made by them as shall be necessary to cause such purchasing Lender to share the excess payment or other recovery ratably with each of them; provided, however, that, if all or any portion of the excess payment or other recovery is thereafter recovered from such purchasing Lender or Issuing Bank, the purchase shall be rescinded and each Lender that has sold a participation to the purchasing Lender or Issuing Bank shall repay to the purchasing Lender or Issuing Bank the purchase price to the ratable extent of such recovery together with an amount equal to such selling Lender’s ratable share (according to the proportion of (x) the amount of such selling Lender’s required repayment to the purchasing Lender or Issuing Bank to (y) the total amount so recovered from the purchasing Lender or Issuing Bank) of any interest or other amount paid or payable by the purchasing Lender or Issuing Bank in respect of the total amount so recovered. The Borrower agrees that any Lender or Issuing Bank so purchasing a participation from another Lender pursuant to this Section 4.17(a) (Sharing of Payments) may, to the fullest extent permitted by law, exercise all its rights of payment (including pursuant to Section 11.13 (Right of Set-off))

 

31


with respect to such participation as fully as if such Lender or Issuing Bank were the direct creditor of the Borrower in the amount of such participation. The provisions of this Section shall not be construed to apply to any payment by the Borrower pursuant to and in accordance with the express terms of this Agreement or any payment obtained by any Lender as consideration for the assignment or sale of a participation in any of its Loans.

(b) If under any applicable bankruptcy, insolvency or other similar law, any Lender receives a secured claim in lieu of a setoff to which this Section 4.17 (Sharing of Payments) applies, such Lender shall, to the extent practicable, exercise its rights in respect of such secured claim in a manner consistent with the rights of the Lenders entitled under this Section 4.17 (Sharing of Payments) to share in the benefits of any recovery on such secured claim.

Section 4.18 Defaulting Lenders.

(a) Notwithstanding anything to the contrary contained in this Agreement, if any Lender becomes a Defaulting Lender, then, until such time as such Lender is no longer a Defaulting Lender, to the extent permitted by applicable Law, any payment of principal, interest, fees or other amounts received by the Credit Facility Agent for the account of such Defaulting Lender (whether voluntary or mandatory, at maturity, pursuant to Article IX (Default and Enforcement) or otherwise) shall be applied at such time or times as may be determined by the Credit Facility Agent as follows: first, to the payment of any amounts owing by such Defaulting Lender to the Credit Facility Agent hereunder or under any other Finance Document; second, to the payment on a pro rata basis of any amounts owing by such Defaulting Lender to any Issuing Bank hereunder; third, to cash collateralize the Issuing Banks’ Fronting Exposure, if any, with respect to such Defaulting Lender in accordance with the procedures set forth in Section 9.03(a) (Action Upon Event of Default); fourth, as the Borrower may request (so long as no Loan Facility Event of Default or Unmatured Loan Facility Event of Default exists), to the funding of any Advance or Loan in respect of which such Defaulting Lender has failed to fund its portion thereof as required by this Agreement, as determined by the Credit Facility Agent; fifth, if so determined by the Credit Facility Agent and the Borrower, to be held in a deposit account and released pro rata in order to (x) satisfy such Defaulting Lender’s potential future funding obligations with respect to Advances or Loans under this Agreement and (y) cash collateralize the Issuing Banks’ future Fronting Exposure, if any, with respect to such Defaulting Lender with respect to future Letters of Credit issued under this Agreement in accordance with the procedures set forth in Section 9.03(a) (Action Upon Event of Default); sixth, to the payment of any amounts owing to the Lenders or the Issuing Banks as a result of any judgment of a court of competent jurisdiction obtained by any Lender or any Issuing Bank against such Defaulting Lender as a result of such Defaulting Lender’s breach of its obligations under this Agreement; seventh, so long as no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is continuing, to the payment of any amounts owing to the Borrower as a result of any judgment of a court of competent jurisdiction obtained by the Borrower against such Defaulting Lender as a result of such Defaulting Lender’s breach of its obligations under this Agreement; and eighth, to such Defaulting Lender or as otherwise directed by a court of competent jurisdiction; provided that, if (x) such payment is a payment of the principal amount of any Loans in respect of which such Defaulting Lender has not fully funded its appropriate share, and (y) such Loans were made or the related Letters of Credit were issued at a time when

 

32


the conditions set forth in Section 7.01 (Conditions to Closing), Section 7.02 (Conditions to Each Term Loan Advance) or Section 7.03 (Conditions to Each Working Capital Advance), as applicable, were satisfied or waived, such payment shall be applied solely to pay the Loans owed to all Non-Defaulting Lenders on a pro rata basis prior to being applied to the payment of any Loans owed to such Defaulting Lender until such time as all Loans and funded and unfunded participations in Letters of Credit are held by the Lenders pro rata in accordance with their applicable Commitments without giving effect to Section 4.18(b). Any payments, prepayments or other amounts paid or payable to a Defaulting Lender that are applied (or held) to pay amounts owed by a Defaulting Lender or to post cash collateral pursuant to this Section 4.18 shall be deemed paid to and redirected by such Defaulting Lender, and such Defaulting Lender irrevocably consents hereto.

(b) All or any part of such Defaulting Lender’s participation in LC Exposure shall be reallocated pro rata among the Non-Defaulting Lenders in accordance with their respective Commitment Percentages (calculated without regard to such Defaulting Lender’s Working Capital Commitment) but only to the extent that (i) the conditions set forth in Section 4.3(c) (Conditions to Each Advance under the Working Capital Facility – Absence of Default) and Section 4.3(d) (Conditions to Each Advance under the Working Capital Facility – Representations and Warranties) of the Common Terms Agreement are satisfied at the time of such reallocation, and (ii) such reallocation does not cause the sum of the outstanding principal amount of the Working Capital Loans, LC Loans and the LC Exposure of any Non-Defaulting Lender to exceed such Non-Defaulting Lender’s Working Capital Commitment. No reallocation hereunder shall constitute a waiver or release of any claim of any party hereunder against a Defaulting Lender arising from that Lender having become a Defaulting Lender, including any claim of a Non-Defaulting Lender as a result of such Non-Defaulting Lender’s increased exposure following such reallocation. If the reallocation described in this Section 4.18(b) cannot, or can only partially, be effected, the Borrower shall, without prejudice to any right or remedy available to it hereunder or under law, cash collateralize the Issuing Banks’ Fronting Exposure on account of such Defaulting Lender (after giving effect to partial reallocations) in accordance with the procedures set forth in Section 9.03(a) (Action Upon Event of Default); provided that, the Borrower shall have sixty (60) days from receipt of written notice by the Credit Facility Agent that the reallocation described in this Section 4.18(b) cannot, or can only partially, be effected, to cash collateralize the Issuing Banks’ Fronting Exposure in accordance with this Section 4.18(b), so long as no Loan Facility Event of Default shall have occurred and be continuing during such period.

(c) If the Borrower, the Credit Facility Agent and the Issuing Banks agree in writing that a Lender is no longer a Defaulting Lender, the Credit Facility Agent will so notify the parties hereto, whereupon as of the effective date specified in such notice and subject to any conditions set forth therein (which may include arrangements with respect to any cash collateral), that Lender will, to the extent applicable, purchase at par that portion of outstanding Loans of the other Lenders or take such other actions as the Credit Facility Agent may determine to be necessary to cause the Loans and funded and unfunded participations in Letters of Credit to be held pro rata by the Lenders in accordance with the relative amounts of their applicable Commitments (without giving effect to Section 4.18(b)), whereupon such Lender will cease to be a Defaulting Lender; provided that, no adjustments will be made retroactively with respect to

 

33


fees accrued or payments made by or on behalf of the Borrower while that Lender was a Defaulting Lender; and provided further that, except to the extent otherwise expressly agreed by the affected parties, no change hereunder from Defaulting Lender to Non-Defaulting Lender will constitute a waiver or release of any claim of any party hereunder arising from that Lender’s having been a Defaulting Lender.

(d) So long as any Lender is a Defaulting Lender, no Issuing Bank shall be required to issue, amend, extend, renew or increase any Letter of Credit to the extent the reallocation described in Section 4.18(b) cannot be effected or the Borrower has not cash collateralized such Issuing Bank’s Fronting Exposure with respect to such Defaulting Lender.

ARTICLE V

LIBOR AND TAX PROVISIONS

Section 5.01 LIBOR Lending Unlawful. In the event that it becomes unlawful or, by reason of a Change in Law, any Lender is prohibited from making or maintaining LIBOR Loans, then such Lender will promptly notify the Borrower of such event (with a copy to the Credit Facility Agent and Intercreditor Agent) and such Lender’s obligation to make or to continue LIBOR Loans, or to convert Base Rate Loans into LIBOR Loans, as the case may be, shall be suspended until such time as such Lender is not prohibited from making and maintaining LIBOR Loans. During such period of suspension, the Loans that would otherwise be made by such Lender as LIBOR Loans shall be made instead by such Lender as Base Rate Loans and each LIBOR Loan made by such Lender and outstanding will automatically, on the last day of the then existing Interest Period therefor if such Loan may lawfully remain outstanding until the end of such Interest Period, and otherwise immediately, convert into a Base Rate Loan. At the Borrower’s request, each Lender shall use reasonable efforts, including using reasonable efforts to designate a different lending office for funding or booking its Loans or to assign its rights and obligations under the Finance Documents to another of its offices, branches or Affiliates, if, in the reasonable judgment of such Lender, such designation or assignment (i) would eliminate or avoid such illegality and (ii) would not subject such Lender to any unreimbursed cost or expense and would not otherwise be disadvantageous to such Lender. The Borrower shall pay all reasonable costs and expenses incurred by any Lender in connection with any such designation or assignment.

Section 5.02 Inability to Determine LIBOR. If prior to the commencement of any Interest Period for a LIBOR Loan:

(a) the Credit Facility Agent reasonably determines that adequate and reasonable means do not exist for ascertaining LIBOR for such Interest Period; or

(b) the Credit Facility Agent is advised by the Required Lenders that such Required Lenders have reasonably determined that LIBOR for such Interest Period will not adequately and fairly reflect the cost to such Lenders of making or maintaining their LIBOR Loans for such Interest Period;

 

34


then the Credit Facility Agent shall give notice thereof to the Borrower and the Lenders by telephone or telecopy as promptly as practicable thereafter and, until the Credit Facility Agent notifies the Borrower and the Lenders that the circumstances giving rise to such notice no longer exist (which notice of subsequent change in circumstances shall be given as promptly as practicable), (i) any Interest Period Notice that requests the conversion of any Loan to, or continuation of any Loan as, a LIBOR Loan shall be ineffective and such Loan shall be converted to a Base Rate Loan on the last day of the Interest Period applicable thereto, and (ii) if any Disbursement Request requests a LIBOR Loan, such Loan shall be made as a Base Rate Loan, or, at the election of the Borrower (upon receipt of the determination to be made by the Required Lenders and only if they are able to agree on such a determination), made as a Loan bearing interest at such rate as the Required Lenders shall determine adequately reflects the costs to the Lenders of making such Loans. The Credit Facility Agent shall promptly give notice to the Borrower, the Lenders and the Intercreditor Agent when the circumstances that gave rise to such notice no longer exist and, in such event, any outstanding Base Rate Loans may be converted, on the last day of the then current Interest Period, to LIBOR Loans.

Section 5.03 Increased Costs.

(a) If any Lender or Issuing Bank incurs additional costs or suffers a reduction, in each case, as described in Section 22.1(a) (Increased Costs) of the Common Terms Agreement, the Borrower shall compensate such Lender or Issuing Bank in accordance with Section 22.1(a) (Increased Costs) of the Common Terms Agreement (except to the extent the Borrower is excused from payment pursuant to Section 5.04 (Obligation to Mitigate)). In determining the amount of such compensation, such Lender or Issuing Bank may, subject to Section 22.1(e) (Increased Costs) of the Common Terms Agreement, use any method of averaging and attribution that it (in its sole discretion) shall deem appropriate.

(b) If any Lender or Issuing Bank or Lender’s or Issuing Bank’s holding company has suffered or would suffer a reduced rate of return as described in Section 22.1(b) (Increased Costs) of the Common Terms Agreement, the Borrower shall compensate such Lender or Issuing Bank or (without duplication) such Lender’s or Issuing Bank’s holding company in accordance with Section 22.1(b) (Increased Costs) of the Common Terms Agreement (except to the extent the Borrower is excused from payment pursuant to Section 5.04 (Obligation to Mitigate)).

(c) To claim any amount under this Section 5.03 (Increased Costs), the Credit Facility Agent or a Lender or Issuing Bank, as applicable, shall promptly deliver a certificate in accordance with Section 22.1(c) (Increased Costs) of the Common Terms Agreement (with a copy to the Credit Facility Agent, if delivered by a Lender or Issuing Bank). The Borrower shall pay the Credit Facility Agent or Lender or Issuing Bank, as applicable, in accordance with Section 22.1(c) (Increased Costs) of the Common Terms Agreement.

(d) Promptly after the Credit Facility Agent or Lender or Issuing Bank, as applicable, has determined that it will make a request for increased compensation pursuant to this Section 5.03 (Increased Costs), such Person shall notify the Borrower thereof (with a copy to the Credit Facility Agent and the Intercreditor Agent). Failure or delay on the part of the Credit Facility Agent or Lender or Issuing Bank to demand compensation pursuant to this Section 5.03

 

35


(Increased Costs) shall not constitute a waiver of such Person’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Person pursuant to this Section 5.03 (Increased Costs) for any increased costs or reductions outside of the period referred to in Section 22.1(d) (Increased Costs) of the Common Terms Agreement.

(e) Notwithstanding any other provision in this Agreement, no Lender or Issuing Bank shall demand compensation pursuant to this Section 5.03 (Increased Costs) in the circumstances described in Section 22.1(e) (Increased Costs) of the Common Terms Agreement.

Section 5.04 Obligation to Mitigate.

(a) If any Lender or Issuing Bank requests compensation under Section 5.03 (Increased Costs), or if the Borrower is required to pay any additional amount to any Lender or Issuing Bank or any Governmental Authority for the account of any Lender or Issuing Bank pursuant to Section 5.06 (Taxes), then such Lender or Issuing Bank shall have an obligation to mitigate such compensation in accordance with Section 19.5(a) (Mitigation Obligations; Replacement of Lenders) of the Common Terms Agreement.

(b) The Borrower may require a Lender or Issuing Bank to assign and delegate (in accordance with and subject to the restrictions contained in Section 11.04 (Assignments)) its interests, rights and obligations under this Agreement and the related Finance Documents in accordance with Section 19.5(c) (Mitigation Obligations; Replacement of Lenders) of the Common Terms Agreement. Nothing in this Section shall be deemed to prejudice any rights that the Borrower, the Credit Facility Agent or any Lender or any Issuing Bank may have against any Lender or Issuing Bank that is a Defaulting Lender. Notwithstanding anything in this section to the contrary, any Working Capital Lender that acts as an Issuing Bank may not be replaced hereunder at any time it has any Letter of Credit outstanding hereunder unless arrangements satisfactory to such Working Capital Lender (including the furnishing of a backstop standby letter of credit in form and substance, and issued by an issuer, reasonably satisfactory to such Issuing Bank and/or the depositing of cash collateral into a cash collateral account in amounts and pursuant to arrangements reasonably satisfactory to such Issuing Bank) have been made with respect to such outstanding Letter of Credit.

Section 5.05 Funding Losses. In the event of (a) the payment of any principal of any LIBOR Loan other than on the last day of an Interest Period applicable thereto (including as a result of a Loan Facility Event of Default), (b) the conversion of any LIBOR Loan other than on the last day of the Interest Period applicable thereto, (c) the failure to borrow, convert, continue or prepay any LIBOR Loan on the date specified in any notice delivered pursuant hereto (other than through any default by the relevant Lender seeking reimbursement) or (d) the assignment of any LIBOR Loan other than on the last day of the Interest Period applicable thereto as a result of a request by the Borrower pursuant to Section 5.04 (Obligation to Mitigate) (a “Breakage Event”), then, in any such event, the Borrower shall compensate each Lender for the Breakage Costs. Such Breakage Costs shall be determined by the Credit Facility Agent based upon the information delivered to it by such Lender. To claim any amount under this Section 5.05 (Funding Losses), the Credit Facility Agent shall promptly deliver to the Borrower a certificate setting forth in reasonable detail any amount or amounts that the applicable Lender is entitled to

 

36


receive pursuant to this Section 5.05 (Funding Losses) (including calculations, in reasonable detail, showing how the Credit Facility Agent computed such amount or amounts), which certificate shall be based upon the information delivered to the Credit Facility Agent by such Lender. The Borrower shall pay to the Credit Facility Agent for the benefit of the applicable Lender the amount due and payable and set forth on any such certificate within 30 days after receipt thereof.

Section 5.06 Taxes. Any and all payments on account of any Loan Obligations shall be made in accordance with the provisions of Article 21 (Tax Gross-up and Indemnities) of the Common Terms Agreement.

Section 5.07 Effect of Benchmark Transition Event.

(a) Benchmark Replacement. Notwithstanding anything to the contrary herein or in any other Finance Document, upon the occurrence of a Benchmark Transition Event or an Early Opt-in Election, as applicable, the Credit Facility Agent and the Borrower may amend this Agreement to replace LIBOR with a Benchmark Replacement. Any such amendment with respect to a Benchmark Transition Event will become effective at 5:00 p.m. New York City time on the fifth (5th) Business Day after the Credit Facility Agent has posted such proposed amendment to all Lenders and the Borrower so long as the Credit Facility Agent has not received, by such time, written notice of objection to such amendment from Lenders comprising the Required Lenders. Any such amendment with respect to an Early Opt-in Election will become effective on the date that Lenders comprising the Required Lenders have delivered to the Credit Facility Agent written notice that such Required Lenders accept such amendment. No replacement of LIBOR with a Benchmark Replacement pursuant to this Section 5.07 (Effect of Benchmark Transition Event) will occur prior to the applicable Benchmark Transition Start Date.

(b) Benchmark Replacement Conforming Changes. In connection with the implementation of a Benchmark Replacement, the Credit Facility Agent, with the written consent of the Borrower (such consent not to be unreasonably withheld, conditioned or delayed), will have the right to make Benchmark Replacement Conforming Changes from time to time and, notwithstanding anything to the contrary herein or in any other Finance Document, any amendments implementing such Benchmark Replacement Conforming Changes will become effective without any further action or consent of any other party to this Agreement.

(c) Notices; Standards for Decisions and Determinations. The Credit Facility Agent will promptly notify the Borrower and the Lenders of (i) any occurrence of a Benchmark Transition Event or an Early Opt-in Election, as applicable, and its related Benchmark Replacement Date and Benchmark Transition Start Date, (ii) the implementation of any Benchmark Replacement, (iii) the effectiveness of any Benchmark Replacement Conforming Changes and (iv) the commencement or conclusion of any Benchmark Unavailability Period. Any determination, decision or election that may be made by the Credit Facility Agent or Lenders pursuant to this Section 5.07 (Effect of Benchmark Transition Event) including any determination with respect to a tenor, rate or adjustment or of the occurrence or non-occurrence of an event, circumstance or date and any decision to take or refrain from taking any action, will be conclusive and binding absent manifest error and may be made in its or their sole discretion

 

37


and without consent from any other party hereto, except, in each case, as expressly required pursuant to this Section 5.07 (Effect of Benchmark Transition Event).

(d) Benchmark Unavailability Period. Upon the Borrower’s receipt of notice of the commencement of a Benchmark Unavailability Period, the Borrower may revoke any request for an Advance of, conversion to or continuation of LIBOR Loans to be made, converted or continued during any Benchmark Unavailability Period and, failing that, the Borrower will be deemed to have converted any such request into a request for an Advance of or conversion to Base Rate Loans. During any Benchmark Unavailability Period, the component of the Base Rate based upon LIBOR will not be used in any determination of the Base Rate.

ARTICLE VI

REPRESENTATIONS AND WARRANTIES

Section 6.01 Incorporation of Common Terms Agreement. The representations and warranties of the Obligors set forth in Article 5 (Representations and Warranties of Obligors) of the Common Terms Agreement have been made to and for the benefit of each of the Lenders and shall apply mutatis mutandis to this Article VI as if fully set forth herein.

ARTICLE VII

CONDITIONS PRECEDENT

Section 7.01 Conditions to Closing. The occurrence of the Closing, the effectiveness of the Lenders’ Commitments, the obligation of each of the Lenders to make available its Initial Advance and the obligation of the Issuing Banks to issue any Letters of Credit on the Closing Date shall be subject to the satisfaction (or waiver by each of the Lenders and each of the Issuing Banks) of each of the conditions precedent set forth in Section 4.1 (Conditions to Closing Date and Initial Advance) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.01 (Conditions to Closing) as if fully set forth herein.

Section 7.02 Conditions to Each Term Loan Advance. The obligation of each Term Lender to make any Advance of Term Loans (whether from the Base Term Loan Commitment or Contingency Reserve Term Loan Commitment) shall be subject to the satisfaction (or waiver by the Credit Facility Agent acting on the instruction of the Required Term Lenders), prior to the making of such Advance, of each of the conditions precedent (and in the case of any Advance of Term Loans other than the Initial Advance, no others) set forth in Section 4.2 (Conditions to Each Advance) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.02 (Conditions to Each Term Loan Advance) as if fully set forth herein.

Section 7.03 Conditions to Each Working Capital Advance.

The obligation of (i) any Issuing Bank to issue Letters of Credit (or extend the maturity thereof (other than any automatic extension thereunder) or modify or amend the terms thereof)

 

38


and (ii) the Working Capital Lenders to make available Working Capital Loans, in each case, subsequent to the Closing Date is subject to the satisfaction (or waiver by the Credit Facility Agent acting on the instruction of the Required Working Capital Lenders and the relevant Issuing Banks, as applicable), prior to issuing such Letter of Credit (or extension, modification or amendment thereof) or to the making of such Working Capital Advance, of each of the conditions precedent set forth in Section 4.3 (Conditions to Each Advance under the Working Capital Facility) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.03 (Conditions to Each Working Capital Advance) as if fully set forth herein.

Section 7.04 Conditions to Occurrence of the Project Completion Date.

The occurrence of the Project Completion Date is subject to the satisfaction of each of the conditions (or waiver by the Credit Facility Agent acting on the instruction of the Required Lenders) of the conditions precedent set forth in Section 14.1 (Conditions to Occurrence of the Project Completion Date) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.04 (Conditions to Occurrence of the Project Completion Date) as if fully set forth herein.

ARTICLE VIII

COVENANTS

Section 8.01 Covenants. The covenants of the Obligors set forth in Article 6 (Incurrence of Additional Senior Debt), Article 7 (Permitted Development Expenditures/Expansions), Article 8 (LNG SPA Covenants), Article 9 (Material Construction Contracts), Article 10 (Reporting by the Borrower), Article 11 (Restricted Payments), Article 12 (Obligors Covenants), Article 13 (Consultants), Section 14.2 (Project Completion Date Waterfall) and Article 20 (Subordination) the Common Terms Agreement have been made to and for the benefit of each of the Lenders and shall apply mutatis mutandis to this Article VIII as if fully set forth herein.

ARTICLE IX

DEFAULT AND ENFORCEMENT

Section 9.01 Events of Default. The occurrence of any Loan Facility Event of Default under the Common Terms Agreement shall constitute an event of default under this Agreement, subject to all of the relevant provisions of the Common Terms Agreement.

Section 9.02 Acceleration Upon Bankruptcy. If any Loan Facility Event of Default described in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement occurs, all outstanding Commitments, if any, shall automatically terminate and the outstanding principal amount of the outstanding Loans and all other Loan Obligations shall automatically be and become immediately due and payable, in each case without notice, demand or further act of the Credit Facility Agent, the Lenders, the Intercreditor Agent, the

 

39


Collateral Agent or any other Credit Facility Secured Party in accordance with Section 16.1(b) (Facility Lender Remedies for Loan Facility Declared Events of Default - Initiating Percentage for Enforcement Action with Respect to Collateral) of the Common Terms Agreement.

Section 9.03 Action Upon Event of Default.

(a) If any Loan Facility Event of Default under the Common Terms Agreement or this Agreement occurs and is Continuing, the Lenders and the Issuing Banks may, by decision of the Required Lenders (i) instruct the Credit Facility Agent, as Senior Creditor Group Representative for the Lenders and the Issuing Banks, to further instruct the Intercreditor Agent to declare that a Loan Facility Declared Default has occurred under this Agreement in accordance with Section 15.2(a) (Declaration of Loan Facility Declared Default) of the Common Terms Agreement and (ii) thereafter, subject to the Intercreditor Agreement and the Common Security and Account Agreement, exercise, or instruct the Intercreditor Agent to exercise, any Enforcement Action provided under Section 16.1 (Facility Lender Remedies for Loan Facility Declared Events of Default) of the Common Terms Agreement (including, subject to the Common Terms Agreement and the Common Security and Account Agreement, requiring the Borrower to deposit with the Credit Facility Agent an amount in the LC Cash Collateral Account equal to one hundred two percent (102%) of the amount available to be drawn under all Letters of Credit then outstanding), each of which is incorporated by reference and shall apply mutatis mutandis to this Section 9.03 (Action Upon Event of Default) as if fully set forth herein; provided that nothing herein shall, upon the occurrence of a Loan Facility Event of Default under Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement, require any certification, declaration or other notice prior to the deemed declaration of such Loan Facility Declared Default or the acceleration of the Loans in connection with the occurrence thereof as provided under Section 16.1(b) (Facility Lender Remedies for Loan Facility Declared Events of Default - Initiating Percentage for Enforcement Action with Respect to Collateral) of the Common Terms Agreement.

(b) Subject to Section 10.5 (Certain Agreements with Respect to Bankruptcy) of the Common Security and Account Agreement, following commencement of any Bankruptcy Proceeding by or against either Obligor or Pledgor any Lender may: (1) file a claim or statement of interest with respect to (and to the extent of) the Senior Debt Obligations (if any) owed by such person to such Lender or Issuing Bank in accordance with the Finance Documents, (2) vote on any plan of reorganization and (3) make other filings, arguments, objections and motions in connection with such Bankruptcy Proceeding, in each case in accordance with the terms of the Finance Documents (other than any requirement for an intercreditor vote to take such action).

(c) Any termination and acceleration made pursuant to this Section 9.03 (Action Upon Event of Default) and Section 16.1(a)(ii) (Facility Lender Remedies for Loan Facility Declared Event of Default – Enforcement Action) of the Common Terms Agreement may, should the Required Lenders in their sole and absolute discretion so elect, be rescinded by written notice to the Borrower at any time after the principal of the Loans has become due and payable, but before any judgment or decree for the payment of the monies so due, or any part thereof, has been entered; provided that, no such rescission or annulment shall extend to or affect any subsequent Loan Facility Event of Default or impair any right consequent thereon.

 

40


(d) An event of default under this Credit Facility Agreement shall be deemed to be declared, in respect of any Loan Facility Event of Default referred to in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement, immediately and automatically upon its occurrence, without the requirement for any certification, declaration or other notice from an Term Lender or the Intercreditor Agent or any Senior Creditor in accordance with Section 15.2(a) (Declaration of Loan Facility Declared Default) of the Common Terms Agreement.

(e) Promptly after any Lender obtains knowledge of any Loan Facility Event of Default, such Lender shall notify the Credit Facility Agent in writing of such Loan Facility Event of Default, which notice shall describe such Loan Facility Event of Default in reasonable detail (including the date of occurrence of the same), specifically refer to this Section 9.03(e) (Action Upon Event of Default) and indicate that such notice is a notice of default.

Section 9.04 Cash Collateralization of Letters of Credit. Subject to the Common Terms Agreement and the Common Security and Account Agreement:

(a) Amounts held in the LC Cash Collateral Account shall be the property of the Credit Facility Agent for the benefit of the Issuing Banks and Working Capital Lenders and shall be applied by the Credit Facility Agent to the repayment of LC Loans deemed made under any Letters of Credit.

(b) The balance, if any, in the LC Cash Collateral Account, after all Letters of Credit shall have expired or been fully drawn upon and giving effect to the payment of any LC Loans pursuant to Section 9.04(a), shall be applied to repay the other Loan Obligations according to Section 9.05 (Application of Proceeds).

Section 9.05 Application of Proceeds. Subject to the terms of the Intercreditor Agreement, any moneys received by the Credit Facility Agent from the Collateral Agent after the occurrence and during the continuance of a Loan Facility Event of Default and the period during which remedies have been initiated shall be applied in full or in part by the Credit Facility Agent against the Loan Obligations in accordance with Section 6.7(b) (Enforcement Proceeds Account) of the Common Security and Account Agreement (but without prejudice to the right of the Lenders or the Issuing Banks, subject to the terms of the Intercreditor Agreement, to recover any shortfall from the Borrower).

ARTICLE X

THE CREDIT FACILITY AGENT

Section 10.01 Appointment and Authority.

(a) Each of the Lenders and each of the Issuing Banks hereby appoints, designates and authorizes Natixis, New York Branch as its Credit Facility Agent under and for purposes of each Finance Document to which the Credit Facility Agent is a party, and in its capacity as the Credit Facility Agent, to act on its behalf as Senior Creditor Group Representative and the Designated Voting Party (as defined in the Intercreditor Agreement) for the Lenders and Issuing

 

41


Banks. Natixis, New York Branch hereby accepts this appointment and agrees to act as the Credit Facility Agent for the Lenders and Issuing Banks in accordance with the terms of this Agreement. Each Lender and Issuing Bank hereby appoints and authorizes the Credit Facility Agent to execute and enter into each of the Common Terms Agreement, Intercreditor Agreement and Common Security and Account Agreement, and each other Finance Document to which it is party, on behalf of such Lender and such Issuing Bank, in its name, place and stead, to bind it to the representations, warranties, terms and conditions contained therein and to act on behalf of such Lender or such Issuing Bank under each Finance Document to which it is a party and in the absence of other written instructions from the Required Lenders received from time to time by the Credit Facility Agent (with respect to which the Credit Facility Agent agrees that it will comply, except as otherwise provided in this Section 10.01 or as otherwise advised by counsel, and subject in all cases to the terms of the Intercreditor Agreement), to exercise such powers hereunder and thereunder as are specifically delegated to or required of the Credit Facility Agent by the terms hereof and thereof, together with such powers as may be reasonably incidental thereto. Where the Credit Facility Agent is required or permitted to act under this Agreement or under any other Finance Document, the Credit Facility Agent shall, notwithstanding anything herein or therein to the contrary, (i) be entitled to request instruction or direction in respect of any such rights, powers and discretions or clarification of any written instruction received by it, as to whether, and in what manner, it should exercise or refrain from exercising its rights, powers and discretions and (ii) unless the terms of the agreement unambiguously mandate the action, may refrain from acting (and will incur no liability in refraining to act) until that direction, instruction or clarification is received by it from the relevant parties or from a court of competent jurisdiction. Without limiting the generality of the foregoing sentence, the use of the term “agent” in this Agreement with reference to the Credit Facility Agent is not intended to connote any fiduciary or other implied (or express) obligations arising under agency doctrine of any applicable Government Rule. Instead, such term is used merely as a matter of market custom, and is intended to create or reflect only an administrative relationship between independent contracting parties.

(b) Except to the extent that the Credit Facility Agent is acting on express instructions, the Credit Facility Agent shall exercise such of the rights and powers vested in it by this Agreement, and use the same degree of care and skill in their exercise as a prudent Person would exercise or use under the circumstances in the conduct of his or her own affairs (taking into account the interests of all the Lenders and Issuing Banks benefiting from this Agreement). Nothing in this Agreement or any other Finance Document shall, in any case in which the Credit Facility Agent has failed to show such degree of care and skill, exempt the Credit Facility Agent from or indemnify it against any liability arising out of its own gross negligence, fraud or willful misconduct in relation to its duties under this Agreement or any other Finance Document as determined by a court of competent jurisdiction in a final non-appealable judgment.

(c) The Credit Facility Agent may not begin any legal action or proceeding in the name of a Lender or Issuing Bank, except as specifically permitted under the terms of this Agreement or the other Finance Documents.

 

42


(d) The provisions of this Article X are solely for the benefit of the Credit Facility Agent and the Term Lenders, and neither the Borrower nor any other Person shall have rights as a third party beneficiary of any of such provisions other than the Borrower’s rights under Section 10.07(a) and (b) (Resignation or Removal of Credit Facility Agent) and Section 10.13 (Agreement to Comply with Finance Documents).

Section 10.02 Rights as a Facility Lender or Hedging Bank. Each Person serving as the Credit Facility Agent hereunder or under any other Finance Document shall have the same rights and powers in its capacity as a Facility Lender or Hedging Bank, as the case may be, as any other Facility Lender or Hedging Bank, as the case may be, and may exercise the same as though it were not the Credit Facility Agent. Each such Person and its Affiliates may accept deposits from, lend money to, act as the financial advisor or in any other advisory capacity for and generally engage in any kind of business with the Borrower or Affiliates of the Borrower as if such Person were not the Credit Facility Agent hereunder and without any duty to account therefor to the Lenders and Issuing Banks.

Section 10.03 Exculpatory Provisions.

(a) The Credit Facility Agent shall not have any duties or obligations except those expressly set forth herein and in the other Finance Documents. Without limiting the generality of the foregoing, the Credit Facility Agent shall not:

(i) be subject to any fiduciary or other implied duties (except for an implied covenant of good faith), regardless of whether a Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing;

(ii) have any duty to take any discretionary action or exercise any discretionary powers, except discretionary rights and powers expressly contemplated hereby or by the other Finance Documents that the Credit Facility Agent is required to exercise as directed in writing by the Required Lenders (or such other number or percentage of the Lenders as shall be expressly provided for herein or in the other Finance Documents); provided that the Credit Facility Agent shall not be required to take any action that, in its opinion or the opinion of its counsel, may expose the Credit Facility Agent to liability or that is contrary to any Finance Document or applicable Government Rule; or

(iii) except as expressly set forth herein and in the other Finance Documents, have any duty to disclose, nor shall the Credit Facility Agent be liable for any failure to disclose, any information relating to the Borrower or any of its Affiliates that is communicated to or obtained by the Person serving as the Credit Facility Agent or any of its Affiliates in any capacity.

(b) The Credit Facility Agent shall not be liable for any action taken or not taken by it (i) with the prior written consent or at the request of the Required Lenders (or such other number or percentage of the Lenders or the Issuing Banks as may be necessary, or as the Credit Facility Agent may believe in good faith to be necessary, under the circumstances as provided in Section 11.01 (Decisions; Amendments, Etc.)) or (ii) in the absence of its own gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction by a final and

 

43


non-appealable order. The Credit Facility Agent shall not be deemed to have knowledge or notice of the occurrence of any Loan Facility Event of Default unless the Credit Facility Agent has received a written notice in accordance with Section 9.03(d) (Action Upon Event of Default) or with Section 2.4(d) (Defaults) of the Intercreditor Agreement or from the Intercreditor Agent, the Obligors, the Pledgor or a Senior Creditor Group Representative referring to this Credit Facility Agreement, describing events or actions constituting a Loan Facility Event of Default and indicating that such notice is a notice of default. If the Credit Facility Agent receives such a notice of the occurrence of any Loan Facility Event of Default, the Credit Facility Agent shall give notice thereof to the Lenders, the Issuing Banks and the Intercreditor Agent. Subject to Article 16 (Common Remedies and Enforcement) of the Common Terms Agreement, the Credit Facility Agent shall take such action with respect to such Loan Facility Event of Default as is provided in Article IX (Default and Enforcement).

(c) The Credit Facility Agent shall not be responsible for or have any duty to ascertain or inquire into (i) any statement, warranty or representation made in or in connection with this Agreement or any other Finance Document, (ii) the contents of any certificate, report or other document delivered hereunder or thereunder or in connection herewith or therewith, (iii) the performance or observance of any of the covenants, agreements or other terms or conditions set forth herein or therein or the occurrence or Continuance of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default, (iv) the validity, enforceability, effectiveness or genuineness of this Agreement, any other Finance Document or any other agreement, instrument or document, or the perfection or priority of any Lien or security interest created or purported to be created by any Security Document, (v) the nature or sufficiency of any payment received by the Credit Facility Agent, or to present or file any claim or notice, or to take any action with respect to the Collateral or any part thereof or the moneys due or to become due in respect thereof or any property covered thereby, or (vi) the satisfaction of any condition set forth in Article VII (Conditions Precedent) or elsewhere herein, other than to confirm receipt of any items expressly required to be delivered to the Credit Facility Agent, except those irregularities or errors of which the Credit Facility Agent has actual knowledge, and provided that nothing herein shall constitute a waiver by any Obligor or any Lender or any Issuing Banks of any of their rights against the Credit Facility Agent as a result of its gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final non-appealable judgment. If any remittance or communication received by the Credit Facility Agent appears manifestly erroneous or irregular to the Credit Facility Agent, it shall be under a duty to make prompt inquiry to the Person originating such remittance or communication in order to determine whether a clerical error or inadvertent mistake has occurred.

(d) The Credit Facility Agent shall not be liable to the Obligors for any breach by any Lender or any Issuing Bank of this Agreement or any other Finance Document (other than by the Facility Agent’s own gross negligence, willful misconduct or fraud as determined by a court of competent jurisdiction in a final and nonappealable judgment) or be liable to any Lender or any Issuing Bank for any breach by any Obligor of this Agreement or any other Finance Document.

 

44


Section 10.04 Reliance by Credit Facility Agent.

(a) The Credit Facility Agent shall be entitled to rely upon, and shall not incur any liability for relying upon, any notice, request, certificate, consent, statement, instrument, document or other writing (including any electronic message, internet or intranet website posting or other distribution) believed by it to be genuine and to have been signed, sent or otherwise authenticated by the proper Person. The Credit Facility Agent also may rely upon any statement made to it orally or by telephone and believed by it to have been made by the proper Person, and shall not incur any liability for relying thereon. In determining compliance with any condition hereunder to the making of a Loan or issuance of a Letter of Credit that by its terms must be fulfilled to the satisfaction of each Lender, each Issuing Bank or the Required Lenders, the Credit Facility Agent may presume that such condition is satisfactory to such Lender, such Issuing Bank or the Required Lenders, as the case may be, unless the Credit Facility Agent has received notice to the contrary from such Lender, such Issuing Bank or the Required Lenders or the Intercreditor Agent prior to the making of such Loan or issuance of such Letter of Credit. The Credit Facility Agent may consult with legal counsel, independent accountants and other experts selected by it, and shall not be liable for any action taken or not taken by it in accordance with the advice of any such counsel, accountants or experts. The Credit Facility Agent shall not be responsible for the negligence or misconduct of any legal counsel, independent accountants and other experts selected by it in good faith, and shall not be required to make any investigation as to the accuracy or sufficiency of any such advice or services; provided that nothing herein shall constitute a waiver by the Obligors, the Lenders or the Issuing Banks of any of their rights against (A) the Credit Facility Agent as a result of its gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final, non-appealable judgment or (B) such counsel, accountants or other experts.

(b) Each Obligor, each Lender and each Issuing Bank shall deliver to the Credit Facility Agent (or, in the case of the Obligors, deliver to the Intercreditor Agent for delivery to each Facility Agent) a list of authorized signatories, together, in the case of the Obligors, with a certificate of an officer of such party certifying the names and true signatures of such authorized signatories who are authorized to sign any notice, certificate, instrument, demand, request, direction, instruction, waiver, receipt, consent, agreement or other document or communication furnished to the Credit Facility Agent hereunder or under the other Finance Documents and the Credit Facility Agent shall be entitled to rely conclusively on such list until a new list is furnished by an Obligor, a Lender or an Issuing Bank, as the case may be, to the Credit Facility Agent (or, in the case of the Obligors, to the Intercreditor Agent for delivery to each Facility Agent).

Section 10.05 Delegation of Duties. The Credit Facility Agent may perform any and all of its duties and exercise any and all its rights and powers hereunder or under any other Finance Document by or through any one or more sub-agents appointed by the Credit Facility Agent. The Credit Facility Agent and any such sub-agent may perform any and all of its duties and exercise its rights and powers by or through their respective Related Parties. The exculpatory provisions of this Article X shall apply to any such sub-agent and to the Related Parties of the Credit Facility Agent, and shall apply to all of their respective activities in connection with their acting as or for the Credit Facility Agent.

 

45


Section 10.06 Indemnification by the Lenders. Without limiting the obligations of the Obligors hereunder or under the other Finance Documents, each Lender agrees that it shall, from time to time on demand by the Credit Facility Agent, indemnify the Credit Facility Agent and its Related Parties (ratably in accordance with its then applicable proportionate share) for any and all liabilities, obligations, losses, damages, penalties, actions, judgments, suits, costs, expenses (including reasonable legal fees) or disbursements of any kind or nature whatsoever, which may at any time be imposed on, incurred by or asserted against the Credit Facility Agent or any of its Related Parties in any way relating to or arising out of this Agreement, the other Finance Documents or any documents contemplated by or referred to herein or therein or the transactions contemplated hereby or thereby or the enforcement of any of the terms hereof or thereof or of any such other documents; provided, however, that no Lender shall be liable for any of the foregoing to the extent they arise solely from the Credit Facility Agent’s gross negligence, fraud or willful misconduct as determined by a final non-appealable judgment of a court of competent jurisdiction. The Credit Facility Agent shall be fully justified in taking, refusing to take or continuing to take any action hereunder unless it shall first be indemnified to its satisfaction by the Lenders against any and all liability and expense which may be incurred by it by reason of taking, refusing to take or continuing to take any such action. Without limitation of the foregoing, each Lender agrees to reimburse, ratably in accordance with all its Loan Commitments, the Credit Facility Agent promptly upon demand for any out-of-pocket expenses (including counsel fees) incurred by the Credit Facility Agent in connection with the preparation, execution, administration, amendment, waiver, modification or enforcement of, or legal advice in respect of rights or responsibilities under, the Finance Documents, to the extent that the Credit Facility Agent is not reimbursed promptly for such expenses by the Obligors in accordance with the Finance Documents; provided that upon recovery of any or all of such costs and expenses by the Credit Facility Agent from the Obligors, the Credit Facility Agent shall remit to each Lender that has paid such costs and expenses to the Credit Facility Agent pursuant to this Section 10.06 (Indemnification by the Lenders) its ratable share of such amounts so recovered. The obligation of the Lenders to make payments pursuant to this Section 10.06 (Indemnification by the Lenders) is several and not joint or joint and several, and the same shall survive the payment in full of the Loan Obligations and the termination of this Agreement and the other Finance Documents.

Section 10.07 Resignation or Removal of Credit Facility Agent.

(a) The Credit Facility Agent may resign from the performance of all its functions and duties hereunder and under the other Finance Documents at any time by giving thirty (30) days’ prior notice to the Borrower, the Lenders and the Issuing Banks. The Credit Facility Agent may be removed at any time (i) by the Required Lenders for such Person’s gross negligence, fraud or willful misconduct or (ii) by the Borrower, with the consent of the Required Lenders and so long as no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing, for such Person’s gross negligence, fraud or willful misconduct. In the event Natixis, New York Branch is no longer the Credit Facility Agent, any successor Credit Facility Agent may be removed at any time with cause by the Required Lenders. Any such resignation or removal shall take effect upon the appointment of a successor Credit Facility Agent, in accordance with this Section 10.07 (Resignation or Removal of Credit Facility Agent) and Section 19.3 (Replacement of Facility Agents) of the Common Terms Agreement.

 

46


(b) Upon any notice of resignation by the Credit Facility Agent or upon the removal of the Credit Facility Agent by the Required Lenders, or by the Borrower with the approval of the Required Lenders pursuant to Section 10.07(a) (Resignation or Removal of Credit Facility Agent), the Required Lenders shall appoint a successor Credit Facility Agent, hereunder and under each other Finance Document to which the Credit Facility Agent is a party, such successor Credit Facility Agent to be a commercial bank or financial institution having combined capital and surplus of at least $1,000,000,000; provided that, if no Loan Facility Event of Default or Unmatured Loan Facility Event of Default shall then be Continuing, the appointment of a successor Credit Facility Agent shall also be subject to the prior written consent of the Borrower (such acceptance not to be unreasonably withheld, conditioned or delayed). The fees payable by the Borrower to a successor Credit Facility Agent shall be the same as those payable to its predecessor unless otherwise agreed between the Borrower and such successor.

(c) If no successor Credit Facility Agent shall have been so appointed and shall have accepted such appointment within sixty (60) days after (i) the retiring Credit Facility Agent gives notice of its resignation or (ii) the date fixed for such removal, as applicable, the Credit Facility Agent shall, at the expense of the Obligors, petition any court of competent jurisdiction in the United States for the appointment of a successor Credit Facility Agent. Such court may thereupon, after such notice, if any, as it may prescribe, appoint a successor Credit Facility Agent. If no successor Credit Facility Agent shall have been so appointed in accordance with clauses (a) and (b) above or (A) this clause (c) and shall have accepted such appointment within ninety (90) days or (B) in the case of this clause (c) if the Credit Facility Agent, acting reasonably, cannot determine a court of competent jurisdiction in the United States that will consider the petition contemplated in this clause (c) within sixty (60) days, in each case after (x) the retiring Credit Facility Agent gives notice of its resignation or (y) the date fixed for such removal, as applicable, the Credit Facility Agent may, at the expense of the Obligors, appoint a successor Credit Facility Agent meeting the criteria set forth in Section 10.07(b) (Resignation or Removal of Credit Facility Agent.); provided that, if no Loan Facility Event of Default shall then be Continuing, the appointment of such successor Credit Facility Agent shall also be subject to the prior written consent of the Borrower (such acceptance not to be unreasonably withheld, conditioned or delayed); provided, further, that if no successor Credit Facility Agent shall have been so appointed by the Credit Facility Agent within thirty (30) days after the termination of such 90-day period, the Obligors may appoint a successor Credit Facility Agent with the consent of the Required Lenders (such consent not to be unreasonably withheld or delayed).

(d) Upon the acceptance of a successor’s appointment as Credit Facility Agent hereunder and compliance with the provisions of Section 19.3 (Replacement of Facility Agents) of the Common Terms Agreement, such successor shall succeed to and become vested with all of the rights, powers, privileges and duties of the retiring (or removed) Credit Facility Agent, and the retiring (or removed) Credit Facility Agent shall be discharged from all of its duties and obligations hereunder or under the other Finance Documents. After the retirement or removal of the Credit Facility Agent hereunder and under the other Finance Documents, the provisions of this Article X and Section 11.07 (Indemnification by the Borrower) shall continue in effect for the benefit of such retiring (or removed) Person, its sub-agents and their respective Related Parties in respect of any actions taken or omitted to be taken by any of them while the retiring Person was acting in its capacity as Credit Facility Agent.

 

47


(e) Notwithstanding anything in this Agreement, no resignation or, as the case may be, removal of the Credit Facility Agent shall be effective until the following conditions are satisfied:

(i) the Credit Facility Agent has transferred to its successor all the rights and obligations in its capacity as Credit Facility Agent under this Credit Facility Agreement, the Common Terms Agreement and the other Finance Documents to which it is party as the Credit Facility Agent; and

(ii) the requirements of Section 19.3 (Replacement of Facility Agents) of the Common Terms Agreement have been satisfied.

Section 10.08 No Amendment to Duties of Credit Facility Agent Without Consent. The Credit Facility Agent shall not be bound by any waiver, amendment, supplement or modification of this Agreement or any other Finance Document that affects its rights or duties hereunder or thereunder unless such Credit Facility Agent shall have given its prior written consent, in its capacity as Credit Facility Agent thereto.

Section 10.09 Non-Reliance on Credit Facility Agent, Lenders and Issuing Banks. Each of the Lenders and Issuing Banks acknowledges that it has, independently and without reliance upon the Credit Facility Agent, any other Lender or Issuing Bank or any of their Related Parties and based on such documents and information as it has deemed appropriate, made its own credit analysis and decision to enter into this Agreement and make its extensions of credit. Each of the Lenders and Issuing Banks also acknowledges that it will, independently and without reliance upon the Credit Facility Agent or any other Lender or Issuing Bank or any of their Related Parties and based on such documents and information as it shall from time to time deem appropriate, continue to make its own decisions in taking or not taking action under or based upon this Agreement, any other Finance Document or any related agreement or any document furnished hereunder or thereunder.

Section 10.10 No Initial Coordinating Lead Arranger, Coordinating Lead Arranger or Documentation Bank Duties. Anything herein to the contrary notwithstanding, no Initial Coordinating Lead Arranger, Coordinating Lead Arranger or Documentation Bank shall have any powers, duties or responsibilities under this Agreement, except in its capacity, as applicable, as the Credit Facility Agent or Lender or Issuing Bank hereunder.

Section 10.11 Copies. The Credit Facility Agent shall give prompt notice to each Lender and each Issuing Bank of receipt of each notice or request required or permitted to be given to the Credit Facility Agent by the Obligors pursuant to the terms of this Agreement or any other Finance Document (unless concurrently delivered to the Lenders by such Obligor). The Credit Facility Agent will distribute to each Lender and each Issuing Bank each document or instrument (including each document or instrument delivered by the Obligors to the Credit Facility Agent pursuant to Article VI (Representations and Warranties), Article VII (Conditions Precedent) and Article VIII (Covenants)) received for the account of the Credit Facility Agent and copies of all other communications received by the Credit Facility Agent from the Obligors for distribution to the Lenders and the Issuing Banks by the Credit Facility Agent in accordance with the terms of this Agreement or any other Finance Document.

 

48


Section 10.12 General Provisions as to Payments.

(a) Subject to Section 4.16 (Pro Rata Treatment), the Credit Facility Agent promptly shall distribute to each Lender and each Issuing Bank its pro rata share of each payment of (a) principal and interest payable to the Lenders or Issuing Banks on the Loans, (b) fees hereunder received by the Credit Facility Agent for the account of the Lenders or the Issuing Banks and (c) any other Loan Obligations. The payments made for the account of each Lender and each Issuing Bank shall be made and distributed to such Lender or Issuing Bank for the account of its facility office set forth in the Common Terms Agreement. Each Lender and each Issuing Bank shall have the right to alter its designated facility office upon written notice to the Credit Facility Agent, the Obligors and the Intercreditor Agent pursuant to Section 11.10 (Notices and Other Communications).

(b) Where a sum is to be paid to a Lender or Issuing Bank under the Finance Documents or another party to this Agreement by another party to this Agreement that is primarily liable for such sum, the Credit Facility Agent shall not be obliged to pay such sum to such other party (or to enter into or perform any related exchange contract) until it has established to its satisfaction that it has received such sum.

(c) If the Credit Facility Agent pays an amount to another party to this Agreement and it proves to be the case that the Credit Facility Agent had not actually received that amount for which another party to this Agreement is primarily liable, then the party to whom that amount (or the proceeds of any related exchange contract) was paid by the Credit Facility Agent shall on demand refund the same to the Credit Facility Agent together with interest on that amount from the date of payment to the date of receipt by the Credit Facility Agent, calculated by the Credit Facility Agent to reflect its cost of funds.

(d) The Credit Facility Agent acknowledges and agrees that, notwithstanding any provision to the contrary in any Finance Document, in no event shall the Lenders or Issuing Banks be obligated to pay any agency or other fee to the Credit Facility Agent even if the Obligors fail to do so.

Section 10.13 Agreement to Comply with Finance Documents. Each of the Lenders and Issuing Banks agrees for the benefit of the Borrower and each other that, in giving instructions to the Credit Facility Agent and the Intercreditor Agent and, where so permitted under this Agreement, the Intercreditor Agreement, Common Terms Agreement or the Common Security and Account Agreement, in taking Decisions by itself or through the Credit Facility Agent, including pursuing any Lender or Issuing Bank remedies against the Borrower, that such Lender or Issuing Bank shall act at all times in accordance with the terms of the Intercreditor Agreement, the Common Security and Account Agreement, the Common Terms Agreement, this Agreement and the applicable Finance Documents.

 

49


ARTICLE XI

MISCELLANEOUS PROVISIONS

Section 11.01 Decisions; Amendments, Etc.

(a) Subject to the terms of the Intercreditor Agreement and the Common Security and Account Agreement, no Modification or termination of any provision of this Agreement or other Decision by Lenders or Issuing Banks under this Agreement shall be effective unless in writing signed by the Obligors and Credit Facility Agent (acting on the instruction of the Required Lenders), and each such Modification, termination or Decision shall be effective only in the specific instance and for the specific purpose for which given; provided that:

(i) the consent of each Lender or each Issuing Bank directly and adversely affected thereby will be required with respect to:

(A) increases in or extensions (other than pursuant to Section 2.09 (Incremental Commitments) or with respect to incurrence of any Additional Senior Debt to which such Lender has agreed to participate) of or change to the order of application of any reduction in any Commitments or change to the order of application of any prepayment of Loans from the application thereof set forth in the applicable provisions of Section 2.07 (Termination or Reduction of Commitments), Section 4.11 (Voluntary Prepayment), Section 4.12 (Mandatory Prepayment) (it being understood that a waiver of any of the conditions in Section 7.01 (Conditions to Closing), Section 7.02 (Conditions to Each Term Loan Advance) or Section 7.03 (Conditions to Each Working Capital Advance) or waiver of any Loan Facility Event of Default, Unmatured Loan Facility Event of Default or mandatory prepayment will not constitute an increase or extension of any Commitment);

(B) reductions of the principal of, or the interest or rate of interest specified herein on, any Loan, or any Fees or other amounts (including reduction in the amount to be paid in respect of any mandatory prepayments under Section 4.12 (Mandatory Prepayment)) payable to any Lender hereunder (other than by virtue of a waiver of any of the conditions in Section 7.01 (Conditions to Closing), Section 7.02 (Conditions to Each Term Loan Advance) or Section 7.03 (Conditions to Each Working Capital Advance), Loan Facility Event of Default or Unmatured Loan Facility Event of Default or change to a financial ratio);

(C) extensions of the Final Maturity Date or Working Capital Loan Termination Date under this Agreement, any date scheduled for any payment of principal, fees, interest or amortization payment (as applicable) under Section 4.01 (Repayment of Term Loan Advances), Section 4.04 (Interest Payment Dates) or Section 4.15 (Fees) or mandatory payment under Section 4.12 (Mandatory Prepayment) (it being understood that a waiver of any condition precedent or the waiver of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default or change to a financial ratio will not constitute an extension of the Final Maturity Date); and

 

50


(D) Modifications to the provisions of Section 4.16 (Pro Rata Treatment) or Section 4.17 (Sharing of Payments);

(ii) the consent of each Lender and each Issuing Bank will be required with respect to:

(A) changes to any provision of this Section 11.01, the definition of Required Lenders, or any other provision hereof specifying the number or percentage of Lenders or Issuing Banks required to amend, waive, terminate or otherwise modify any rights hereunder or make any determination or grant any consent hereunder;

(B) releases or Modifications of all or a material portion of the Collateral from the Lien of any of the Security Documents (other than as permitted in the Finance Documents);

(C) releases of all or a substantial portion of the value of the Guarantee by the Guarantor under or in connection with this Agreement, the Common Terms Agreement, the Common Security and Account Agreement or any Security Document (other than as permitted in the Finance Documents);

(D) assignment or transfer by any Obligor of any of its rights and obligations under this Agreement except with respect to any such assignment or transfer expressly permitted under this Agreement, the Common Terms Agreement or the Common Security and Account Agreement;

(E) any of the amendments contemplated in Schedule 1(a), (b), (c), (d), (e), (f), (g), (h) and (i) (All Loan Facilities Decisions) of the Intercreditor Agreement; provided, that the consent of all Lenders will be required with respect to Schedule 1(b) (All Loan Facilities Decisions) of the Intercreditor Agreement only to the extent such amendment adversely affects the timing or priority of payments for Senior Debt Obligations in the cash waterfall in Section 4.7 (Cash Waterfall) of the Common Security and Account Agreement; and

(F) satisfaction or waiver of each of the conditions in Section 7.01 (Conditions to Closing); and

(iii) the consent of any Lender (other than any Lender that is an Obligor, the Pledgor or the Sponsor or an Affiliate thereof except as set forth in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement) will be sufficient with respect to any Modification, termination or Decision specified in a Finance Document as being made solely by any individual Senior Creditor.

 

51


(b) Except as set forth in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, no Lender that is an Obligor or the Sponsor or an Affiliate thereof shall cast a vote with respect to any Decision.

(c) In the event that the Credit Facility Agent is required to cast a vote with respect to a Decision under this Agreement or under Section 3.6 (Other Voting Considerations) of the Intercreditor Agreement and in each other instance in which the Lenders or Issuing Banks are required to vote or make a Decision, a vote shall be taken among the Lenders or Issuing Banks in the timeframe reasonably specified by the Credit Facility Agent (which timeframe shall expire at least two (2) Business Days prior to the expiration of the time period specified in the notice provided by the Intercreditor Agent to the Credit Facility Agent pursuant to Section 4.5(a)(iii) (Certain Procedures Relating to Modifications, Instructions, and Exercises of Discretion) of the Intercreditor Agreement).

(d) No vote shall be required for any Decision or other action permitted to be taken by any individual Lender or any individual Issuing Bank pursuant to Section 9.03(b) (Action Upon Event of Default) of this Agreement, and the Credit Facility Agent shall be authorized to act at the direction of any Lender or any Issuing Bank in respect of any such Decision or action.

(e) Subject to clause (f) below, in the event any Lender or any Issuing Bank does not cast its votes by the later of (i) the timeframe specified by the Credit Facility Agent pursuant to clause (c) above and (ii) ten (10) Business Days following receipt of the request for such vote or Decision, the Borrower shall be entitled to instruct the Credit Facility Agent to deliver a notice to such Lender or Issuing Bank, informing it that if it does not respond within an additional five (5) Business Days of the date of such notice (or such longer period as the Borrower may reasonably determine in consultation with the Credit Facility Agent), its vote shall be disregarded. If such Lender or Issuing Bank (A) has not advised the Credit Facility Agent within the time specified in the additional notice whether it approves or disapproves of the applicable Decision or (B) has advised the Credit Facility Agent that it has determined to abstain from voting on such Decision, such Lender or Issuing Bank shall be deemed to have waived its right to consent, approve, waive or provide direction with respect to such Decision and shall be excluded from the numerator and denominator of such calculation for the purpose of determining whether the Required Lenders for the purpose of determining whether the Required Lenders have made a decision with respect to such action. Such Lender hereby waives any and all rights it may have to object to or seek relief from the decision of the Lenders voting with respect to such issue and agrees to be bound by such decision.

(f) The provisions of (c) and (e) above do not apply to any action that requires the consent of 100% of the Lenders or Issuing Banks or the consent of each affected Lender and Issuing Bank, as applicable, as set forth in Section 11.01(a)(i) and (ii) (Decisions; Amendments, Etc.) above.

 

52


(g) The agreements contemplated by this Section 11.01 (Decisions; Amendments, Etc.) shall not be required for any update to the Amortization Schedule delivered in accordance with Section 4.01(a) (Repayment of Term Loans) (which amendments shall be effective, absent any manifest error, upon delivery by the Credit Facility Agent to the Borrower and Intercreditor Agent of the updated Amortization Schedule in accordance with the provisions of that Section).

(h) With respect to any modification, consent or waiver under any Finance Document requiring the vote of the Credit Facility Agent as Senior Creditor Group Representative of the Lenders and the Issuing Banks, such vote will be cast in accordance with the Intercreditor Agreement.

(i) Notwithstanding anything herein, in the Common Terms Agreement or in the Common Security and Account Agreement to the contrary, the Lenders or Issuing Banks, or the Credit Facility Agent as Senior Credit Group Representative, shall not be entitled to vote on any covenant or event of default in the Common Terms Agreement if such covenant or event of default expressly does not extend to the Lenders or the Issuing Banks under the terms of this Agreement.

(j) Notwithstanding anything herein, each of the Lenders and Issuing Banks authorizes and instructs the Credit Facility Agent to make Administrative Decisions (as defined in the Intercreditor Agreement) with respect to the Credit Facility Agreement without the need for further authorization, consent or instruction from any Lender, Issuing Bank or other Credit Facility Secured Party with respect to such Administrative Decisions.

Section 11.02 Entire Agreement. This Agreement, the other Finance Documents and any agreement, document or instrument attached hereto or referred to herein integrate all the terms and conditions mentioned herein or incidental hereto and supersede all oral negotiations and prior writings in respect to the subject matter hereof.

Section 11.03 Applicable Government Rule; Jurisdiction; Etc.

(a) GOVERNING LAW. THIS AGREEMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK.

(b) SUBMISSION TO JURISDICTION. The provisions set forth in Section 23.14 (Consent to Jurisdiction) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

(c) Service of Process. Each party irrevocably consents to the service of any and all process in any such action or proceeding by the mailing of copies of such process to such Person at its then effective notice addresses pursuant to Section 11.10 (Notices and Other Communications).

(d) Immunity. The provisions set forth in Section 23.3 (Waiver of Immunity) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

(e) WAIVER OF JURY TRIAL. The provisions set forth in Section 23.13 (Waiver of Jury Trial) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

 

53


Section 11.04 Assignments.

(a) The provisions of this Agreement shall be binding upon and inure to the benefit of the parties hereto and their respective successors and assigns permitted hereby, except that none of the Obligors may assign or otherwise transfer any of its rights or obligations hereunder without the prior written consent of each of the Lenders, each of the Issuing Banks and the Credit Facility Agent (and any attempted assignment or other transfer by any Obligor without such consent shall be null and void), and no Lender or Issuing Bank may assign or otherwise transfer any of its rights or obligations hereunder except (i) to an Acceptable Lender in accordance with Section 11.04(b) and Section 11.04(i), (ii) by way of participation in accordance with Section 11.04(d) – (f) or (iii) by way of pledge or assignment of a security interest subject to the restrictions of Section 11.04(g) (and any other attempted assignment or transfer by any party hereto shall be null and void).

(b) (i) Subject to Section 11.04(i), Section 11.04(j) and this Section 11.04(b), any Lender may at any time after the date hereof assign to one or more Acceptable Lenders all or a portion of its rights and obligations under this Agreement (including all or a portion of its Commitments and the Loans at the time owing to it and, if such Loans are LC Loans, an equal portion of its Non-Fronting Limit); provided that, during the Availability Period for any Type of Loans or Commitments subject to assignment, (x) any such Acceptable Lender is an Eligible Assignee or has a then-current credit rating of at least equivalent to Baa2 from Moody’s or BBB from S&P or, if applicable, an insurer whose financial strength rating is at least equivalent to Baa1 from Moody’s or BBB+ from S&P or is otherwise creditworthy in the opinion of the Borrower (acting reasonably) in light of the Commitments proposed to be assigned, transferred or novated and (y) if the assigning Working Capital Lender is an Issuing Bank, the assignee is an Eligible Assignee or meets the ratings criteria within the definition of Issuing Bank; provided further that, on the date of such assignment, such assignment would not result in an increase in amounts payable by the Borrower under Section 5.03 (Increased Costs) or Section 5.05 (Funding Losses), unless such increase in amounts payable measured on such date of assignment is waived by the assigning and assuming Lenders.

(ii) Assignments made pursuant to this Section 11.04(b) shall be made with the prior written approval of the Borrower (such approval not to be unreasonably withheld or delayed and to be deemed to have been given by the Borrower if the Borrower has not responded in writing within fifteen (15) Business Days of request) unless (A) such assignment is to a Person described in clauses (a) or (b) of the definition of “Eligible Assignee” or (B) a Loan Facility Event of Default has occurred and is Continuing; provided, however, that where the prior written approval of the Borrower is not required, the assigning Existing Facility Lender shall promptly notify the Borrower of any such assignment, novation or transfer.

(iii) Except in the case of (A) an assignment of the entire remaining amount of the assigning Lender’s Commitment of a certain Type and, if such assignment is of a Working Capital Commitment, the Working Capital Loans and LC Loans owing to it and its entire Non-Fronting Limit or (B) an assignment to a Lender, or an Affiliate of a Lender, or an Approved Fund with respect to a Lender, the sum of (1) the outstanding

 

54


Commitments, if any, and (2) the outstanding Loans subject to each such assignment (determined as of the date the Lender Assignment Agreement with respect to such assignment is delivered to the Credit Facility Agent or, if “Trade Date” is specified in the Lender Assignment Agreement, as of the Trade Date) shall not be less than $5,000,000, in the case of Term Loans and Term Loan Commitments, and $1,000,000 in the case of Working Capital Commitments and, with respect to the assignment of the Term Loans, in integral multiples of $1,000,000, and with respect to the assignment of Working Capital Loans, in integral multiples of $500,000, unless the Credit Facility Agent otherwise consents in writing.

(iv) Subject to Section 11.04(g) and Section 11.04(i), each partial assignment shall be made as an assignment of the same percentage of outstanding Commitments and outstanding Loans of the same Type and a proportionate part of all the assigning Lender’s rights and obligations under this Agreement with respect to the Loan and the Commitment of the such Type.

(v) The parties to each assignment shall execute and deliver to the Credit Facility Agent a Lender Assignment Agreement, in the form of Exhibit G (Form of Lender Assignment Agreement), together with a processing and recordation fee of $3,500; provided that (A) no such fee shall be payable in the case of an assignment to a Lender, an Affiliate of a Lender or an Approved Fund with respect to a Lender and (B) in the case of contemporaneous assignments by a Lender to one or more Approved Funds managed by the same investment advisor (which Approved Funds are not then Lenders hereunder), only a single such fee shall be payable for all such contemporaneous assignments.

(vi) If the Acceptable Lender is not a Lender prior to such assignment, it shall deliver to the Credit Facility Agent an administrative questionnaire and all documentation and other information required by bank regulatory authorities under applicable “know your customer” requirements.

(vii) In connection with any assignment of rights and obligations of any Defaulting Lender hereunder, no such assignment shall be effective unless and until, in addition to the other conditions thereto set forth herein, the parties to the assignment shall make such additional payments to the Credit Facility Agent in an aggregate amount sufficient, upon distribution thereof as appropriate (which may be outright payment, purchases by the assignee of participations or subparticipations, or other compensating actions, including funding, with the consent of the Borrower and the Credit Facility Agent, the applicable pro rata share of Loans previously requested but not funded by the Defaulting Lender, to each of which the applicable assignee and assignor hereby irrevocably consent), to (x) pay and satisfy in full all payment liabilities then owed by such Defaulting Lender to the Credit Facility Agent, and each other Lender hereunder (and interest accrued thereon), including any Issuing Bank pursuant to Section 3.02(e) (Reimbursement of Issuing Bank), and (y) acquire (and fund as appropriate) its full pro rata share of all Loans in accordance with its Commitment Percentage. Notwithstanding the foregoing, in the event that any assignment of rights and obligations of any Defaulting Lender hereunder shall become effective under applicable law without compliance with the provisions of this paragraph, then the assignee of such interest shall be deemed to be a Defaulting Lender for all purposes of this Agreement until such compliance occurs.

 

55


(viii) Subject to acceptance and recording thereof by the Credit Facility Agent pursuant to Section 11.04(c), from and after the effective date specified in each Lender Assignment Agreement, the Acceptable Lender thereunder shall be a party to this Agreement and, to the extent of the interest assigned by such Lender Assignment Agreement, have the rights and obligations of a Lender under this Agreement and the other applicable Finance Documents, and the assigning Lender thereunder shall, to the extent of the interest assigned by such Lender Assignment Agreement, be released from its obligations under this Agreement and the other applicable Finance Documents (and, in the case of a Lender Assignment Agreement covering all of the assigning Lender’s rights and obligations under this Agreement, such Lender shall cease to be a party hereto or benefit from any Finance Document) but shall continue to be entitled to the benefits of Section 5.01 (LIBOR Lending Unlawful), Section 5.03 (Increased Costs), Section 5.05 (Funding Losses), Section 5.06 (Taxes), Section 23.4 (Expenses) of the Common Terms Agreement and Section 12.18 (Other Indemnities) of the Common Security and Account Agreement with respect to facts and circumstances occurring prior to the effective date of such assignment; provided that except to the extent otherwise expressly agreed by the affected parties, no assignment by a Defaulting Lender will constitute a waiver or release of any claim of any party hereunder arising from that Lender’s having been a Defaulting Lender.

(ix) Upon request, the Borrower (at its expense) shall execute and deliver a Note to the assignee Lender and/or a revised Note to the assigning Lender reflecting such assignment.

(x) Any assignment or transfer by a Lender of rights or obligations under this Agreement that does not comply with this Section 11.04(b) shall be treated for purposes of this Agreement as a sale by such Lender of a participation in such rights and obligations in accordance with Section 11.04(d) through (f). Any assignment or transfer by an Issuing Bank of rights or obligations under this Agreement that does not comply with this Section 11.04(b) and Section 3.05 (Resignation as an Issuing Bank), as applicable, shall be null and void. Upon any such assignment, the Credit Facility Agent will deliver a notice thereof to the Borrower (provided that failure to deliver such notice shall not result in any liability for the Credit Facility Agent).

(xi) Any assignment of the Base Term Loan Commitment or the Contingency Reserve Term Loan Commitment shall be accompanied by a pro rata assignment of the Contingency Reserve Term Loan Commitment or the Base Term Loan Commitments, respectively.

(c) The Credit Facility Agent shall maintain the Register in accordance with Section 2.06(e) (Funding).

 

56


(d) Any Lender may at any time, without the consent of, or notice to, the Borrower or the Credit Facility Agent, sell participations to a Participant (other than a Disqualified Institution) in all or a portion of such Lender’s rights or obligations under this Agreement (including all or a portion of its Commitments or the Loans under this Agreement owing to it); provided that (i) such Lender’s obligations under this Agreement shall remain unchanged, (ii) such Lender shall remain solely responsible to the other parties hereto for the performance of such obligations and (iii) the Borrower, the Credit Facility Agent and the other Lenders shall continue to deal solely and directly with such Lender in connection with such Lender’s rights and obligations under this Agreement. For the avoidance of doubt, each Lender shall be responsible for the indemnity under Section 10.06 (Indemnification by the Lenders) with respect to any payments made by such Lender to its Participant(s).

(e) Any agreement or instrument pursuant to which a Lender sells such a participation shall provide that such Lender shall retain the sole right to enforce this Agreement and to approve any amendment, modification or waiver of any provision of this Agreement; provided that, such agreement or instrument may provide that such Lender will not, without the consent of the Participant, agree to any amendment, waiver or other modification described in the first proviso to Section 11.01 (Decisions; Amendments, Etc.) that directly affects such Participant. The Borrower agrees that each Participant shall be entitled to the benefits of Sections 5.03 (Increased Costs), 5.05 (Funding Losses) and 5.06 (Taxes) (subject to the requirements and limitations therein and in Article 21 (Tax Gross-Up and Indemnities) of the Common Terms Agreement, including the requirements under Section 21.5 (Status of Facility Lenders and Facility Agents) of the Common Terms Agreement (it being understood that any documentation required under Section 5.06 (Taxes) shall be delivered to the participating Lender)) to the same extent as if it were a Lender and had acquired its interest by assignment pursuant to paragraph (b) of this Section 11.04 (Assignments); provided that such Participant (A) agrees to be subject to the provisions of Section 5.04 (Obligation to Mitigate) as if it were an assignee under paragraph (b) of this Section 11.04; and (B) shall not be entitled to receive any greater payment under Sections 5.03 (Increased Costs) or 5.06 (Taxes), with respect to any participation, than its participating Lender would have been entitled to receive, except to the extent such entitlement to receive a greater payment results from a Change in Law that occurs after the Participant acquired the applicable participation.

(f) Each Lender that sells a participation agrees, at such Lender’s request and expense, to use reasonable efforts to cooperate with the Borrower to effectuate the provisions of Section 5.04 (Obligation to Mitigate) with respect to any Participant. To the extent permitted by law, each Participant also shall be entitled to the benefits of Section 11.13 (Right of Set-off) as though it were a Lender; provided that such Participant agrees to be subject to Section 4.17 (Sharing of Payments) as though it were a Lender. Each Lender that sells a participation shall, acting solely for this purpose as a non-fiduciary agent of the Borrower, maintain a Participant Register; provided that no Lender shall have any obligation to disclose all or any portion of the Participant Register (including the identity of any Participant or any information relating to a Participant’s interest in any commitments, loans or its other obligations under any Finance Document) to any Person except to the extent that such disclosure is necessary to establish that such commitment, loan or other obligation is in registered form under Section 5f.103-1(c) of the United States Treasury Regulations. The entries in the Participant Register shall be conclusive

 

57


absent manifest error, and such Lender shall treat each Person whose name is recorded in the Participant Register as the owner of such participation for all purposes of this Agreement notwithstanding any notice to the contrary. For the avoidance of doubt, the Credit Facility Agent (in its capacity as Credit Facility Agent) shall have no responsibility for maintaining a Participant Register.

(g) Any Lender may at any time pledge or assign a security interest in all or any portion of its rights under this Agreement (including under its Notes, if any) to secure obligations of such Lender, including any pledge or assignment to secure obligations to a Federal Reserve Bank or any central bank having jurisdiction over such Lender in accordance with any applicable law, and this Section 11.04 (Assignments) shall not apply to any such pledge or assignment of a security interest; provided that no such pledge or assignment of a security interest shall release a Lender from any of its obligations hereunder or substitute any such pledgee or assignee for such Lender as a party hereto; provided, further that in no event shall the applicable Federal Reserve Bank, central bank, pledgee or trustee be considered to be a “Lender” or “Issuing Bank”, as applicable.

(h) The words “execution,” “signed,” “signature,” and words of like import in any Lender Assignment Agreement shall be deemed to include electronic signatures or the keeping of records in electronic form, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any applicable Government Rule, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

(i) All assignments by a Lender of all or a portion of its rights and obligations hereunder with respect to then outstanding Commitments of a certain Type shall be made only as an assignment of the same percentage of outstanding Commitments of such Type and outstanding Loans of such Type, and, in the case an assignment of rights and obligations with respect to a Working Capital Commitment, the Non-Fronting Limit under this Agreement held by such Lender. If a Working Capital Lender has no unused Working Capital Commitments, assignments of outstanding Loans owing to such Working Capital Lender may be made, together with a pro rata portion of such Working Capital Lender’s rights and obligations with respect to the Loans subject to such assignment, in such amounts, to such persons and on such terms as are permitted by and otherwise in accordance with Section 11.04(b).

(j) No sale, assignment, transfer, negotiation or other disposition of the interests of any Lender or Issuing Bank hereunder or under the other Finance Documents shall be allowed if it could reasonably be expected to require securities registration under any laws or regulations of any applicable jurisdiction.

(k) Notwithstanding anything to the contrary herein, (i) in no event may any Working Capital Lender assign all or any portion of its Working Capital Loans, Working Capital Commitments, LC Loans or participations in Letters of Credit to an Affiliated Lender and (ii) subject to Section 11.04(b) (Assignments) and so long as no Loan Facility Event of Default has

 

58


occurred and is Continuing, any Term Lender may assign all or any portion of its Term Loans and/or Term Loan Commitments hereunder to any Affiliated Lender (pursuant to an assignment agreement in which such Affiliated Lender shall identify itself), but only if after giving effect to such assignment, Affiliated Lenders shall not, in the aggregate, own or hold Term Loans and Term Loan Commitments with an aggregate principal amount in excess of 25% of the aggregate principal amount of the Term Loans then outstanding and the remaining Term Loan Commitments (calculated as of the date of such purchase) (the “Affiliated Lender Cap”); provided that, to the extent that any assignment to any Affiliated Lender would result in the aggregate principal amount of Term Loans and Term Loan Commitments held by Affiliated Lenders exceeding the Affiliated Lender Cap (after giving effect to any substantially simultaneous cancellation thereof), the assignment of such excess amount shall be null and void. To the extent that any Affiliated Lender holds Term Loans or Term Loan Commitments, no such Affiliated Lender shall (i) except as set forth in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, (A) have any voting or approval rights under the Finance Documents or (B) be permitted to require the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Senior Creditor to undertake any action (or refrain from taking any action) pursuant to or with respect to the Finance Documents, (ii) be permitted to, in its capacity as a Lender, attend any meeting or conference call with the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Senior Creditor unless the Borrower has been invited to attend such conference calls or meetings, receive any information from the Administrative Agent, the Collateral Agent, the Intercreditor Agent, any Lender or any other Senior Creditor unless such information has been made available to the Borrower (other than the right to receive notices of borrowings, notices of prepayments, and other administrative notices in respect of its Term Loans or Term Loan Commitments required to be delivered pursuant to Article II (Commitments and Advances) or Article IV (Repayments, Prepayments, Interest and Fees)) or have any rights of inspection or access relating to any Collateral Party or (iii) be permitted to make or bring any claim, in its capacity as Lender, against the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Lender or Senior Creditor with respect to the duties and obligations of such Person under the Finance Documents other than in the case of a material breach by the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Lender or Senior Creditor to such Affiliated Lender (except with respect to any such breaches applicable to the Lenders generally unless the other Lenders have made or brought such claims).

(l) Each Affiliated Lender, solely in its capacity as a Lender, hereby agrees, that, if any Collateral Party or any of their assets shall be subject to any voluntary or involuntary proceeding commenced under the Bankruptcy Code (“ Bankruptcy Proceedings”), (i) such Affiliated Lender, solely in its capacity as a Lender, shall not take any step or action in such Bankruptcy Proceeding to object to, impede, or delay the exercise of any right or the taking of any action by the Credit Facility Agent (or the taking of any action by a third party that is supported by the Administrative Agent) in relation to such Affiliated Lender’s claim with respect to its Term Loans or Term Commitments (an “Affiliated Lender Claim”) (including, without limitation, objecting to any debtor in possession financing, use of cash collateral, grant of adequate protection, sale or disposition, compromise, or plan of reorganization) so long as such Affiliated Lender is treated in connection with such exercise or action on the same or better terms as the other Lenders and (ii) with respect to any matter requiring the vote of Lenders

 

59


during the pendency of a Bankruptcy Proceeding (including voting on any plan of reorganization), (A) the Advances held by such Affiliated Lender (and any Affiliated Lender Claim with respect thereto) shall be deemed to be voted in such Bankruptcy Proceeding in the same proportion as the allocation of voting with respect to such matter by those Lenders who are not Affiliated Lenders, so long as such Affiliated Lender is treated in connection with the exercise of such right or taking of such action on the same or better terms as the other Lenders and (B) the Affiliated Lenders shall agree that the Credit Facility Agent shall vote on behalf of such Affiliated Lenders. For the avoidance of doubt, the Lenders and each Affiliated Lender, solely in its capacity as a Lender, agrees and acknowledge that the provisions set forth in this Section 11.04(l) constitute a “subordination agreement” as such term is contemplated by, and utilized in, Section 510(a) of the Bankruptcy Code, and, as such, would be enforceable for all purposes in any case where a Collateral Party has filed for protection under the Bankruptcy Code.

Section 11.05 Benefits of Agreement. Nothing in this Agreement or any other Finance Document, express or implied, shall be construed to give to any Person, other than the parties hereto, the Initial Coordinating Lead Arrangers, the Coordinating Lead Arranger, the Documentation Banks and each of their successors and permitted assigns under this Agreement or any other Finance Document, Participants to the extent provided in Section 11.04 (Assignments) and, to the extent expressly contemplated hereby, the Related Parties of each of the Credit Facility Agent, the Collateral Agent, the Lenders and the Issuing Banks, any benefit or any legal or equitable right or remedy under this Agreement.

Section 11.06 Counterparts; Effectiveness. This Agreement may be executed in counterparts (and by different parties hereto in different counterparts), each of which shall constitute an original, but all of which when taken together shall constitute a single contract. This Agreement shall become effective when it has been executed by the Credit Facility Agent and when the Credit Facility Agent has received counterparts hereof that, when taken together, bear the signatures of each of the other parties hereto. Delivery of an executed counterpart of a signature page of this Agreement by portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Agreement.

Section 11.07 Indemnification by the Borrower.

(a) The Obligors hereby agree to indemnify the Credit Facility Agent, each Lender, each Issuing Bank, each Initial Coordinating Lead Arranger, the Coordinating Lead Arranger, each Documentation Bank and each Related Party of any of the foregoing Persons in accordance with Section 12.18 (Other Indemnities) of the Common Security and Account Agreement and Section 2.15 (Other Indemnities) of the Intercreditor Agreement, which shall be applied mutatis mutandis to the indemnified parties under this Agreement, as well as with respect to reliance by such indemnified party on each notice purportedly given by or on behalf of the Borrower pursuant to Section 11.10 (Notices and Other Communications).

 

60


(b) To the extent that any Obligor for any reason fails to pay any amount required under Section 12.18 (Other Indemnities) of the Common Security and Account Agreement or clause (a) above to be paid by it to any of the Credit Facility Agent, any sub-agent thereof or any Related Party of any of the foregoing, each Lender severally agrees to pay to the Credit Facility Agent, any such sub-agent, or such Related Party, as the case may be, such Lender’s ratable share (determined as of the time that the applicable unreimbursed expense or indemnity payment is sought) of such unpaid amount; provided that, the unreimbursed expense or indemnified loss, claim, damage, liability or related expense, as the case may be, was incurred by or asserted against the Credit Facility Agent or any sub-agent thereof in its capacity as such, or against any Related Party of any of the foregoing acting for the Credit Facility Agent or any sub-agent thereof in connection with such capacity. The obligations of the Lenders under this Section 11.07(b) (Indemnification by the Borrower) are subject to the provisions of Section 2.06 (Funding). The obligations of the Lenders to make payments pursuant to this Section 11.07(b) (Indemnification by the Borrower) are several and not joint and shall survive the payment in full of the Loan Obligations and the termination of this Agreement. The failure of any Lender to make payments on any date required hereunder shall not relieve any other Lender of its corresponding obligation to do so on such date, and no Lender shall be responsible for the failure of any other Lender to do so.

(c) The provisions of this Section 11.07 (Indemnification by the Borrower) shall not supersede Sections 5.03 (Increased Costs) and 5.06 (Taxes).

Section 11.08 Interest Rate Limitation. Notwithstanding anything to the contrary contained in any Finance Document, the interest paid or agreed to be paid under the Finance Documents shall not exceed the maximum rate of non-usurious interest permitted by applicable Government Rule (the “Maximum Rate”). If the Credit Facility Agent or any Lender or any Issuing Bank shall receive interest in an amount that exceeds the Maximum Rate, the excess interest shall be applied to the principal of the Loans or, if it exceeds such unpaid principal, refunded to the Borrower. In determining whether the interest contracted for, charged, or received by the Credit Facility Agent or any Lender or Issuing Bank exceeds the Maximum Rate, such Person may, to the extent permitted by applicable Government Rule, (a) characterize any payment that is not principal as an expense, fee, or premium rather than interest, (b) exclude prepayments and the effects thereof, and (c) amortize, prorate, allocate, and spread in equal or unequal parts the total amount of interest throughout the contemplated term of the Loan obligations hereunder.

Section 11.09 No Waiver; Cumulative Remedies. No failure by any Credit Facility Secured Party to exercise, and no delay by any such Person in exercising, any right, remedy, power or privilege hereunder or under any other Finance Document shall operate as a waiver thereof; nor shall any single or partial exercise of any right, remedy, power or privilege hereunder preclude any other or further exercise thereof or the exercise of any other right, remedy, power or privilege. The rights, remedies, powers and privileges herein provided, and provided under each other Finance Document, are cumulative and not exclusive of any rights, remedies, powers and privileges provided by law.

Section 11.10 Notices and Other Communications.

(a) Any communication between the parties hereto or notices provided herein to be given may be given as provided in Section 23.8 (Notices) of the Common Terms Agreement, which shall apply mutatis mutandis to this Section 11.10 (Notices and Other Communications) as if fully set forth herein except that references to the Intercreditor Agent shall be deemed references to the Credit Facility Agent as the context requires.

 

61


(b) The Credit Facility Agent, the Issuing Banks, the Collateral Agent and the Lenders shall be entitled to rely and act upon any written notices purportedly given by or on behalf of the Borrower even if (i) such notices were not made in a manner specified herein, were incomplete or were not preceded or followed by any other form of notice specified herein, or (ii) the terms thereof, as understood by the recipient, varied from any confirmation thereof. All telephonic notices to and other telephonic communications with the Credit Facility Agent, the Collateral Agent, the Issuing Banks and the Lenders by the Borrower may be recorded by the Credit Facility Agent, the Collateral Agent, the Issuing Banks and the Lenders, as applicable, and each of the parties hereto hereby consents to such recording.

(c) Notwithstanding the above, nothing herein shall prejudice the right of the Credit Facility Agent, the Collateral Agent, any of the Issuing Banks and any of the Lenders to give any notice or other communication pursuant to any Finance Document in any other manner specified in such Finance Document.

(d) Notwithstanding anything to the contrary in any other Finance Document, for so long as Natixis, New York Branch is the Credit Facility Agent, the Borrower hereby agrees that it will provide to the Credit Facility Agent all information, documents and other materials that it is obligated to furnish to the Credit Facility Agent pursuant to the Finance Documents, including all notices, requests, financial statements, financial and other reports, certificates and other information materials, but excluding any such communication that (i) relates to any Advance, (ii) relates to the payment of any principal or other amount due under this Agreement prior to the scheduled date therefor, (iii) provides notice of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default or (iv) is required to be delivered to satisfy any condition precedent to any Advance (all such non-excluded communications being referred to herein collectively as “Communications”), in an electronic/soft medium in a format acceptable to the Credit Facility Agent at the email addresses specified in Schedule Q – 2 (Addresses for Notices to Facility Agents and Facility Lenders) of the Common Terms Agreement. In addition, the Borrower agrees to continue to provide the Communications to the Credit Facility Agent in the manner specified in the Finance Documents but only to the extent requested by the Credit Facility Agent.

Section 11.11 USA Patriot Act Notice. Each of the Lenders, the Credit Facility Agent, the Collateral Agent and the Issuing Banks hereby notifies the Borrower that pursuant to the requirements of the USA Patriot Act, it is required to obtain, verify and record information that identifies the Borrower, the Guarantor and the Pledgor, which information includes the name and address of the Borrower and other information that will allow such Lender, the Credit Facility Agent, the Collateral Agent or such Issuing Bank, as applicable, to identify the Borrower, the Guarantor and the Pledgor in accordance with the USA Patriot Act.

Section 11.12 Payments Set Aside. To the extent that any payment by or on behalf of the Borrower is made to the Credit Facility Agent, the Collateral Agent, any Issuing Bank or any

 

62


Lender, or the Credit Facility Agent, the Collateral Agent, any Issuing Bank or any Lender (as the case may be) exercises its right of setoff, and such payment or the proceeds of such setoff or any part thereof is subsequently invalidated, declared to be fraudulent or preferential, set aside or required (including pursuant to any settlement entered into by the Credit Facility Agent, the Collateral Agent, any Issuing Bank or such Lender in its discretion) to be repaid to a trustee, receiver or any other party, in connection with any Bankruptcy Proceeding or otherwise, then (a) to the extent of such recovery, the Loan Obligation or part thereof originally intended to be satisfied by such payment shall be revived and continued in full force and effect as if such payment had not been made or such setoff had not occurred, and (b) each Lender and each Issuing Bank severally agrees to pay to the Credit Facility Agent or the Collateral Agent upon demand its applicable share (without duplication) of any amount so recovered from or repaid by the Credit Facility Agent or the Collateral Agent, as the case may be, plus interest thereon from the date of such demand to the date such payment is made at a rate per annum equal to the Federal Funds Effective Rate from time to time in effect. The obligations of the Lenders and the Issuing Banks under this Section 11.12 (Payments Set Aside) shall survive the payment in full of the Loan Obligations and the termination of this Agreement.

Section 11.13 Right of Set-Off. The provisions set forth in Section 23.2 (Right of Set-Off) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

Section 11.14 Severability. If any provision of this Agreement or any other Finance Document is held to be illegal, invalid or unenforceable, (a) the legality, validity and enforceability of the remaining provisions of this Agreement and the other Finance Documents shall not be affected or impaired thereby and (b) the parties shall endeavor in good faith negotiations to replace the illegal, invalid or unenforceable provisions with valid provisions the economic effect of which comes as close as possible to that of the illegal, invalid or unenforceable provisions. The invalidity of a provision in a particular jurisdiction shall not invalidate or render unenforceable such provision in any other jurisdiction.

Section 11.15 Survival. Notwithstanding anything in this Agreement to the contrary, Section 5.01 (LIBOR Lending Unlawful), Section 5.03 (Increased Costs), Section 5.05 (Funding Losses), Section 5.06 (Taxes), Section 10.06 (Indemnification by the Lenders), Section 11.07 (Indemnification by the Borrower), Section 11.12 (Payments Set Aside) and Section 11.20 (No Recourse) shall survive any termination of this Agreement. In addition, each representation and warranty made hereunder and in any other Finance Document or other document delivered pursuant hereto or thereto or in connection herewith or therewith shall survive the execution and delivery hereof and thereof. Such representations and warranties shall be considered to have been relied upon by the Credit Facility Secured Parties regardless of any investigation made by any Credit Facility Secured Party or on their behalf and notwithstanding that the Credit Facility Secured Parties may have had notice or knowledge of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default at the time of any Advance or Loan hereunder, and shall continue in full force and effect as of the date made or any date referred to herein as long as any Loan or any other Senior Debt Obligation hereunder or under any other Finance Document shall remain unpaid or unsatisfied.

 

63


Section 11.16 Treatment of Certain Information; Confidentiality. The Credit Facility Agent, the Collateral Agent, and each of the Lenders and Issuing Banks agrees to maintain the confidentiality of the Confidential Information and all information disclosed to it concerning this Agreement and the other Finance Documents in accordance with Section 23.7 (Confidentiality) of the Common Terms Agreement.

Section 11.17 Waiver of Consequential Damages, Etc.

(a) The provisions set forth in Section 23.18 (Limitations on Liability) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

(b) No party hereto or its Related Parties shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Finance Documents or the transactions contemplated hereby or thereby.

Section 11.18 Waiver of Litigation Payments. To the extent that any party hereto may, in any action, suit or proceeding brought in any of the courts referred to in Section 11.03(b) (Applicable Government Rule; Jurisdiction, Etc.) or elsewhere arising out of or in connection with this Agreement or any other Finance Document to which it is a party, be entitled to the benefit of any provision of law requiring any other party hereto in such action, suit or proceeding to post security for the costs of such Person or to post a bond or to take similar action, each such Person hereby irrevocably waives such benefit, in each case to the fullest extent now or in the future permitted under the laws of the State of New York or, as the case may be, the jurisdiction in which such court is located.

Section 11.19 Reinstatement. This Agreement shall continue to be effective or be reinstated, as the case may be, if (and only to the extent that) any payment or performance of the obligations of the Borrower hereunder is rescinded, avoided, voidable, liable to be set aside, reduced or otherwise not properly payable to, or must otherwise be returned or restored by the Credit Facility Agent or any Lender or any Issuing Bank as a result of (i) Bankruptcy, insolvency, reorganization with respect to the Borrower or the Credit Facility Agent or any Lender or any Issuing Bank, (ii) upon the dissolution of, or appointment of any intervenor, conservator, trustee or similar official for the Borrower, the Credit Facility Agent or any Lender or any Issuing Bank or for any substantial part of the Borrower’s or any other such Person’s assets, (iii) as a result of any settlement or compromise with any Person (including the Borrower) in respect of such payment or otherwise, or (iv) any similar event or otherwise and, in such case, the provisions of Section 10.1 (Nature of Obligations) of the Common Security and Account Agreement, which shall apply hereto mutatis mutandis.

Section 11.20 No Recourse. The provisions set forth in Section 10.3 ( Limitation on Recourse) of the Common Security and Account Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

 

64


Section 11.21 Intercreditor Agreement. Any actions, consents, approvals, authorizations or discretion taken, given, made or exercised, or not taken, given, made or exercised by the Credit Facility Agent, acting as a Senior Creditor Group Representative on behalf of the Lenders and Issuing Banks, in accordance with the Intercreditor Agreement shall be binding on each Lender and Issuing Bank. Notwithstanding anything to the contrary herein, in the case of any inconsistency between this Agreement and the Intercreditor Agreement, the Intercreditor Agreement shall govern.

Section 11.22 Termination. This Agreement shall terminate and shall have no force and effect (except with respect to the provisions that expressly survive termination of this Agreement) in accordance with the provisions of Section 23.1 (Termination) of the Common Terms Agreement and if the Discharge Date with respect to the Loan Obligations has occurred.

Section 11.23 Acknowledgment and Consent to Bail-In of EEA Financial Institutions.

(a) Notwithstanding anything to the contrary in any Finance Document, each party hereto acknowledges that any liability of any Lender or Issuing Bank that is an EEA Financial Institution arising under any Finance Document, to the extent such liability is unsecured, may be subject to the Write-Down and Conversion Powers of an EEA Resolution Authority and agrees and consents to, and acknowledges and agrees to be bound by:

(i) the application of any Write-Down and Conversion Powers by an EEA Resolution Authority to any such liabilities arising hereunder which may be payable to it by any Lender or Issuing Bank that is an EEA Financial Institution; and

(ii) the effects of any Bail-in Action on any such liability, including, if applicable:

(A) a reduction in full or in part or cancellation of any such liability;

(B) a conversion of all, or a portion of, such liability into shares or other instruments of ownership in such EEA Financial Institution, its parent undertaking, or a bridge institution that may be issued to it or otherwise conferred on it, and that such shares or other instruments of ownership will be accepted by it in lieu of any rights with respect to any such liability under this Agreement or any other Finance Document; or

(b) the variation of the terms of such liability in connection with the exercise of the Write-Down and Conversion Powers of any EEA Resolution Authority.

[Remainder of page intentionally blank. Next page is signature page.]

 

65


IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by their respective officers as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,
as the Borrower
By:    /s/ D. Michael Eberhardt
Name: D. Michael Eberhardt
Title: Chief Financial Officer
TRANSCAMERON PIPELINE, LLC,
as the Guarantor
By:    /s/ D. Michael Eberhardt
Name: D. Michael Eberhardt
Title: Chief Financial Officer

[Signature Page to Credit Facility Agreement]


NATIXIS, NEW YORK BRANCH,
as Credit Facility Agent
By:    /s/ Urs B. Fischer
Name: Urs B. Fischer
Title: Executive Director
By:    /s/ Hana Beckles
Name: Hana Beckles
Title: Director

[Signature Page to Credit Facility Agreement]


MIZUHO BANK (USA),
as Collateral Agent
By:    /s/ Brian Caldwell
Name: Brian Caldwell
Title: Managing Director

[Signature Page to Credit Facility Agreement]


BANCO SANTANDER, S.A., NEW YORK BRANCH,
as a Lender
By:    /s/ Rita Walz-Cuccioli
Name: Rita Walz-Cuccioli

Title: Executive Director Banco Santander,

   S.A., New York Branch

By:    /s/ Xavier Ruiz
Name: Xavier Ruiz
Title: Managing Director

[Signature Page to Credit Facility Agreement]


BANK OF AMERICA, N.A.,
as a Lender and Issuing Bank
By:    /s/ Ronald E. McKaig
Name: Ronald E. McKaig
Title: Managing Director

[Signature Page to Credit Facility Agreement]


THE BANK OF NOVA SCOTIA, HOUSTON BRANCH,
as a Lender
By:    /s/ Alfredo Brahim
Name: Alfredo Brahim
Title: Director

[Signature Page to Credit Facility Agreement]


GOLDMAN SACHS BANK USA,
as a Lender
By:    /s/ Thomas M. Manning
Name: Thomas M. Manning
Title: Authorized Signatory

[Signature Page to Credit Facility Agreement]


INDUSTRIAL AND COMMERCIAL BANK OF CHINA LIMITED, NEW YORK BRANCH,
as a Lender
By:    /s/ Guoshen Sun
Name: Guoshen Sun
Title: Deputy General Manager

[Signature Page to Credit Facility Agreement]


ING CAPITAL LLC,
as a Lender
By:    /s/ Subha Pasumarti
Name: Subha Pasumarti
Title: Managing Director
By:    /s/ Anthony River
Name: Anthony River
Title: Director

[Signature Page to Credit Facility Agreement]


JPMORGAN CHASE BANK, N.A.,
as a Lender
By:    /s/ Travis Watson
Name: Travis Watson
Title: Vice President

[Signature Page to Credit Facility Agreement]


MIZUHO BANK, LTD.,
as a Lender
By:    /s/ Junji Hasegawa
Name: Junji Hasegawa
Title: Managing Director

[Signature Page to Credit Facility Agreement]


MORGAN STANLEY SENIOR FUNDING, INC.,
as a Lender
By:    /s/ Eric Farina
Name: Eric Farina
Title: Managing Director

[Signature Page to Credit Facility Agreement]


NATIXIS, NEWYORK BRANCH,
as a Lender and Issuing Bank
By:    /s/ Nasir Khan
Name: Nasir Khan
Title: Managing Director
By:    /s/ Amit Roy
Name: Amit Roy
Title: Executive Director

[Signature Page to Credit Facility Agreement]


NOMURA CORPORATE FUNDING AMERICAS, LLC,
as a Lender
By:    /s/ Vinod Mukani
Name: Vinod Mukani
Title: Managing Director

[Signature Page to Credit Facility Agreement]


ROYAL BANK OF CANADA,
as a Lender
By:    /s/ Jason S. York
Name: Jason S. York
Title: Authorized Signatory

[Signature Page to Credit Facility Agreement]


SUMITOTO MITSUI BANKING CORPORATION,
as a Lender
By:    /s/ Juan Kreutz
Name: Juan Kreutz
Title: Managing Director

[Signature Page to Credit Facility Agreement]


Final

Schedule I

Lenders, Commitments

Term Loan Commitments1

 

Term Lenders

   Base Term Loan
Commitment
     Contingency Reserve
Term Loan
Commitment
     Aggregate
Term Loan

Commitments
 

Banco Santander, S.A., New York Branch

   $ [***]      $ [***]      $ [***]  

Bank of America, N.A.

   $ [***]      $ [***]      $ [***]  

The Bank of Nova Scotia, Houston Branch

   $ [***]      $ [***]      $ [***]  

Goldman Sachs Bank USA

   $ [***]      $ [***]      $ [***]  

Industrial and Commercial Bank of China Limited, New York Branch

   $ [***]      $ [***]      $ [***]  

ING Capital LLC

   $ [***]      $ [***]      $ [***]  

JPMorgan Chase Bank, N.A.

   $ [***]      $ [***]      $ [***]  

Mizuho Bank, Ltd.

   $ [***]      $ [***]      $ [***]  

Morgan Stanley Senior Funding, Inc.

   $ [***]      $ [***]      $ [***]  

Natixis, New York Branch

   $ [***]      $ [***]      $ [***]  

Nomura Corporate Funding Americas, LLC

   $ [***]      $ [***]      $ [***]  

Royal Bank of Canada

   $ [***]      $ [***]      $ [***]  

 

 

1

Term Loan Commitments have been rounded to the nearest cent for purposes of display on this Schedule I.


Term Lenders

   Base Term Loan
Commitment
     Contingency Reserve
Term Loan
Commitment
     Aggregate Term
Loan
Commitments
 

Sumitomo Mitsui Banking Corporation

   $ [***]      $ [***]      $ [***]  

Total

   $ [***]      $ [***]      $ 5,477,453,873.64  

Working Capital Commitments2

 

Working Capital Lenders

   Total Working Capital
Commitment
 

Banco Santander, S.A., New York Branch

   $ [***]  

Bank of America, N.A.

   $ [***]  

The Bank of Nova Scotia, Houston Branch

   $ [***]  

Goldman Sachs Bank USA

   $ [***]  

Industrial and Commercial Bank of China Limited, New York Branch

   $ [***]  

ING Capital LLC

   $ [***]  

JPMorgan Chase Bank, N.A.

   $ [***]  

Mizuho Bank, Ltd.

   $ [***]  

Morgan Stanley Senior Funding, Inc.

   $ [***]  

Natixis, New York Branch

   $ [***]  

 

 

2

Working Capital Commitments have been rounded to the nearest cent for purposes of display on this Schedule I.

 

Schedule I - 2


Working Capital Lenders

   Total Working Capital
Commitment
 

Nomura Corporate Funding Americas, LLC

   $ [***]  

Royal Bank of Canada

   $ [***]  

Sumitomo Mitsui Banking Corporation

   $ [***]  

Total

   $ 300,000,000.00  

 

Schedule I - 3


Schedule II

Issuing Bank Limits3

 

Issuing Bank

   Fronting
Limit
     Non-Fronting
Limit
     Issuing Bank
Limit
 

Bank of America, N.A.

   $ [***]        [***]      $ 100,000,000  

Natixis, New York Branch

   $ [***]        [***]      $ 300,000,000  

 

 

3 

For the avoidance of doubt, in accordance with Section 3.01(b) of the Credit Facility Agreement (Letters of Credit), no Issuing Bank shall be required to issue any Letter of Credit or any amendment to increase the face or stated amount of any Letter of Credit if, after such issuance or amendment, the aggregate Working Capital Commitment Exposure for all Working Capital Lenders shall exceed the Aggregate Working Capital Commitments, among the other terms and conditions set forth in the Credit Facility Agreement.


Schedule III

Amortization Schedule

[Omitted]


Schedule IV

Credit Facility Agent Account Details

To: [***]

ABA: [***]

Account Name: [***]

Account Number: [***]

Reference: [***]


EXHIBIT A TO

CREDIT FACILITY AGREEMENT

Definitions

Advance” means, as context requires, a Term Loan Advance, a Working Capital Advance, or both.

Advance Date” means, with respect to each Advance, the date on which funds are disbursed by the Lenders (or the Credit Facility Agent on their behalf) to the Borrower.

Affiliated Lender” means Sponsor or any of its Affiliates.

Affiliated Lender Cap” has the meaning specified in Section 11.04(k) (Assignments). “Affiliated Lender Claim” has the meaning specified in Section 11.04(l) (Assignments).

Aggregate Commitments” means, as context requires, the sum of the Term Loan Commitments or the sum of the Working Capital Commitments.

Aggregate Term Loan Commitments” means the sum of the Term Loan Commitments.

Aggregate Working Capital Commitments” means the sum of the Working Capital Commitments.

Agreement” has the meaning provided in the preamble.

Amortization Schedule” means the amortization schedule set forth in Schedule III.

Applicable Margin” means (a) with respect to Loans that are LIBOR Loans, (i) from the Closing Date until the third (3rd) anniversary of the Closing Date, 2.375% per annum, (ii) from the third (3rd) anniversary of the Closing Date until the fifth (5th) anniversary of the Closing Date, 2.625% per annum, and (iii) from the fifth (5th) anniversary of the Closing Date until the Final Maturity Date, 2.875% per annum, and (b) with respect to Loans that are Base Rate Loans, (i) from the Closing Date until the third (3rd) anniversary of the Closing Date, 1.375% per annum, (ii) from the third (3rd) anniversary of the Closing Date until the fifth (5th) anniversary of the Closing Date, 1.625% per annum, and (iii) from the fifth (5th) anniversary of the Closing Date until the Maturity Date, 1.875% per annum.

Availability Period” means, as context requires, the Term Loan Availability Period or the Working Capital Availability Period.

Bankruptcy Proceeding” has the meaning set forth in Section 11.04(l) (Assignments).

Base Rate” means, for any day, a fluctuating rate per annum equal to the highest of (a) the Federal Funds Effective Rate plus 0.50%, (b) the prime rate published in The Wall Street Journal for such day; provided that if The Wall Street Journal ceases to publish for

 

1


any reason such rate of interest, “Base Rate” shall mean the prime lending rate as set forth on the Bloomberg page PRIMBB Index (or successor page) for such day (or such other service as determined by the Credit Facility Agent from time to time for purposes of providing quotations of prime lending interest rates) and (c) the LIBOR for an interest period of one month plus 1.00%; provided that, for purposes of this Agreement, if the Base Rate for any interest period is less than zero percent (0%), it shall be deemed zero percent (0%) for such interest period. “Base Rate Loan” means any Term Loan bearing interest at a rate determined by reference to the Base Rate and the provisions of Article III (Commitments and Advance) and Article IV (Repayments, Prepayments, Interest and Fees).

Base Term Loan Commitment” means the commitment of a Term Lender to make or otherwise fund a Term Loan pursuant to Section 2.01(a)(i) (Term Loans), as set forth opposite the name of such Term Lender in the column entitled “Base Term Loan Commitment” in Schedule I (Lenders, Commitment) or if such Term Lender has entered into one or more Lender Assignment Agreements, set forth opposite the name of such Term Lender and any assignor Term Lender in the Register maintained by the Credit Facility Agent pursuant to Section 2.06(f) (Funding), as the same may be reduced in accordance with Section 2.07 (Termination or Reduction of Commitments), and “Base Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

Benchmark Replacement” means the sum of: (a) the alternate benchmark rate (which may include Term SOFR) that has been selected by the Credit Facility Agent and the Borrower giving due consideration to (i) any selection or recommendation of a replacement rate or the mechanism for determining such a rate by the Relevant Governmental Body or (ii) any evolving or then-prevailing market convention for determining a rate of interest as a replacement to LIBOR for U.S. dollar-denominated syndicated credit facilities and (b) the Benchmark Replacement Adjustment; provided that, if the Benchmark Replacement as so determined would be less than zero, the Benchmark Replacement will be deemed to be zero for the purposes of this Agreement.

Benchmark Replacement Adjustment” means, with respect to any replacement of LIBOR with an Unadjusted Benchmark Replacement for each applicable Interest Period, the spread adjustment, or method for calculating or determining such spread adjustment, (which may be a positive or negative value or zero) that has been selected by the Credit Facility Agent and the Borrower giving due consideration to (i) any selection or recommendation of a spread adjustment, or method for calculating or determining such spread adjustment, for the replacement of LIBOR with the applicable Unadjusted Benchmark Replacement by the Relevant Governmental Body or (ii) any evolving or then-prevailing market convention for determining a spread adjustment, or method for calculating or determining such spread adjustment, for the replacement of LIBOR with the applicable Unadjusted Benchmark Replacement for U.S. dollar-denominated syndicated credit facilities at such time.

Benchmark Replacement Conforming Changes” means, with respect to any Benchmark Replacement, any technical, administrative or operational changes (including changes to the definition of “Base Rate,” the definition of “Interest Period,” timing and frequency of determining rates and making payments of interest and other administrative matters) that the Credit Facility Agent decides, with the consent of the Borrower (not to be unreasonably

 

2


withheld, conditioned or delayed), may be appropriate to reflect the adoption and implementation of such Benchmark Replacement and to permit the administration thereof by the Credit Facility Agent in a manner substantially consistent with market practice (or, if the Credit Facility Agent decides that adoption of any portion of such market practice is not administratively feasible or if the Credit Facility Agent determines that no market practice for the administration of the Benchmark Replacement exists, in such other manner of administration as the Credit Facility Agent decides, with the consent of the Borrower (not to be unreasonably withheld, conditioned or delayed), is reasonably necessary in connection with the administration of this Agreement).

Benchmark Replacement Date means the earlier to occur of the following events with respect to LIBOR:

(1) in the case of clause (1) or (2) of the definition of “Benchmark Transition Event,” the later of (a) the date of the public statement or publication of information referenced therein and (b) the date on which the administrator of LIBOR permanently or indefinitely ceases to provide LIBOR; or

(2) in the case of clause (3) of the definition of “Benchmark Transition Event,” the date of the public statement or publication of information referenced therein.

Benchmark Transition Event means the occurrence of one or more of the following events with respect to LIBOR:

(1) a public statement or publication of information by or on behalf of the administrator of LIBOR announcing that such administrator has ceased or will cease to provide LIBOR, permanently or indefinitely, provided that, at the time of such statement or publication, there is no successor administrator that will continue to provide LIBOR;

(2) a public statement or publication of information by the regulatory supervisor for the administrator of LIBOR, the U.S. Federal Reserve System, an insolvency official with jurisdiction over the administrator for LIBOR, a resolution authority with jurisdiction over the administrator for LIBOR or a court or an entity with similar insolvency or resolution authority over the administrator for LIBOR, which states that the administrator of LIBOR has ceased or will cease to provide LIBOR permanently or indefinitely, provided that, at the time of such statement or publication, there is no successor administrator that will continue to provide LIBOR; or

(3) a public statement or publication of information by the regulatory supervisor for the administrator of LIBOR announcing that LIBOR is no longer representative.

Benchmark Transition Start Date” means (a) in the case of a Benchmark Transition Event, the earlier of (i) the applicable Benchmark Replacement Date and (ii) if such Benchmark Transition Event is a public statement or publication of information of a prospective event, the 90th day prior to the expected date of such event as of such public statement or publication of information (or if the expected date of such prospective event is fewer than 90 days after such statement or publication, the date of such statement or publication) and (b) in the case of an Early Opt-in Election, the date specified by the Credit Facility Agent or the Required Lenders, as applicable, with the consent of the Borrower (not to be unreasonably withheld, conditioned or delayed), by notice to the Credit Facility Agent (in the case of such notice by the Required Lenders) and the Lenders.

 

3


Benchmark Unavailability Period” means, if a Benchmark Transition Event and its related Benchmark Replacement Date have occurred with respect to LIBOR and solely to the extent that LIBOR has not been replaced with a Benchmark Replacement, the period (x) beginning at the time that such Benchmark Replacement Date has occurred if, at such time, no Benchmark Replacement has replaced LIBOR for all purposes hereunder in accordance with Section 5.07 (Effect of Benchmark Transition Event) and (y) ending at the time that a Benchmark Replacement has replaced LIBOR for all purposes hereunder pursuant to Section 5.07 (Effect of Benchmark Transition Event).

Breakage Costs” means the amount (if any) by which:

(a) the interest that would have accrued on the principal amount of a LIBOR Loan had a Breakage Event not occurred calculated at LIBOR that would have been applicable to such LIBOR Loan for the period from the date of such Breakage Event to the last day of the then current Interest Period therefor (or, in the case of a failure to borrow, convert or continue a LIBOR Loan, for the period that would have been the Interest Period for such LIBOR Loan);

exceeds:

(b) the interest that would accrue on such principal amount for such period at the interest rate which the relevant Term Lender would bid were it to bid, at the commencement of such period, for deposits in Dollars of a comparable amount and period from other banks in the LIBOR market.

Breakage Event” has the meaning provided in Section 5.05 (Funding Losses).

Commitment” means, as context requires, a Term Loan Commitment, a Working Capital Commitment or both.

Commitment Fees” has the meaning provided in Section 4.15(b) (Fees).

Commitment Percentage” means (i) as to any Working Capital Lender at any time, the percentage that such Working Capital Lender’s Working Capital Commitment less its Working Capital Commitment Exposure then constitutes of the Aggregate Working Capital Commitment less the total Working Capital Commitment Exposure of all Working Capital Lenders, (ii) as to any Term Lender at any time, the percentage of such Term Lender’s Term Loan Commitment constitutes of the Aggregate Term Loan Commitment and (iii) as to any Issuing Bank at any time, the percentage that such Issuing Bank’s Issuing Bank Limit less the stated amount of Letters of Credit issued by such Issuing Bank then constitutes of the aggregate Issuing Bank Limits for all Issuing Banks less the total stated amount of Letters of Credit issued by all Issuing Banks.

Communications” has the meaning provided in Section 11.10(d) (Notices and Other Communications).

 

4


Contingency Reserve Term Loan Commitment” means the commitment of a Term Lender to make or otherwise fund a Term Loan pursuant to Section 2.01(a)(ii) (Term Loans), as set forth opposite the name of such Term Lender in the column entitled “Contingency Reserve Term Loan Commitment” in Schedule I (Lenders, Commitment) or if such Term Lender has entered into one or more Lender Assignment Agreements, set forth opposite the name of such Term Lender and any assignor Term Lender in the Register maintained by the Credit Facility Agent pursuant to Section 2.06(f) (Funding), as the same may be reduced in accordance with Section 2.07 (Termination or Reduction of Commitments), and “Contingency Reserve Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

Coordinating Lead Arranger” means Industrial and Commercial Bank of China, New York Branch, not in its individual capacity but as coordinating lead arranger hereunder.

Credit Facility Agent” has the meaning provided in the preamble.

Credit Facility Secured Parties” means the Lenders, the Issuing Banks, the Credit Facility Agent, the Collateral Agent and each of their respective successors and permitted assigns, in each case in connection with the Credit Facility Agreement.

Defaulting Lender” means a Lender which (a) has defaulted in its obligations to fund all or any portion of any Term Loan or otherwise failed to comply with its obligations under Section 2.01 (Term Loans), Section 2.03 (Working Capital Loans), Section 2.06 (Funding) or Section 3.02 (Reimbursement to Issuing Banks), unless (x) such default or failure is no longer continuing or has been cured within three (3) Business Days after such default or failure or (y) such Lender notifies the Credit Facility Agent and the Borrower in writing that such failure is the result of such Lender’s good faith determination that one or more conditions precedent to funding (each of which conditions precedent, together with any applicable default, shall be specifically identified in such writing) has not been satisfied, (b) has notified the Borrower and/or the Credit Facility Agent that it does not intend to comply with its obligations under Section 2.01 (Term Loans), Section 2.03 (Working Capital Loans), Section 2.06 (Funding) or Section 3.02 (Reimbursement to Issuing Banks) or has made a public statement to that effect, (c) has failed, within three (3) Business Days, after written request by the Credit Facility Agent or the Borrower, to confirm in writing to the Credit Facility Agent and the Borrower that it will comply with its prospective funding obligations under Section 2.03 (Working Capital Loans), Section 2.06 (Funding) or Section 3.02 (Reimbursement to Issuing Banks) (provided that such Lender shall cease to be a Defaulting Lender pursuant to this clause (c) upon receipt of such written confirmation by the Credit Facility Agent and the Borrower), (d) has, or has a direct or indirect parent company that has, other than via Undisclosed Administration, (x) become the subject of a Bankruptcy Proceeding, or (y) had appointed for it a receiver, custodian, conservator, trustee, administrator, assignee for the benefit of creditors or similar Person charged with reorganization or liquidation of its business or assets, including the Federal Deposit Insurance Corporation or any other state or federal regulatory authority acting in such a capacity or (e) has become the subject of a Bail-In Action; provided that, for the avoidance of doubt, a Lender shall not be a Defaulting Lender solely by virtue of (i) the ownership or acquisition of any equity interest in that Lender or any direct or indirect parent company thereof by a Governmental Authority or (ii) in the case of a solvent Person, the precautionary appointment of an administrator, guardian, custodian or other similar official by a Governmental Authority under

 

5


or based on the law of the country where such Person is subject to home jurisdiction supervision if Government Rule requires that such appointment not be publicly disclosed; in each case, where such action does not result in or provide such Lender with immunity from the jurisdiction of courts within the United States or from the enforcement of judgments or writs of attachment on its assets or permit such Lender (or such Governmental Authority) to reject, repudiate, disavow or disaffirm any contracts or agreements made with such Lender. Any determination by the Credit Facility Agent that a Lender is a Defaulting Lender under any one or more of the clauses above shall be conclusive and binding absent manifest error, and such Lender shall be deemed to be a Defaulting Lender upon delivery of written notice of such determination to the Borrower and each Lender.

Documentation Bank” means Natixis, New York Branch and Sumitomo Mitsui Banking Corporation, in each case, not in its individual capacity, but as documentation bank.

Early Opt-in Election” means the occurrence of:

(1) (i) a determination by the Credit Facility Agent or (ii) a notification by the Required Lenders to the Credit Facility Agent (with a copy to the Borrower) that the Required Lenders have determined that U.S. dollar-denominated syndicated credit facilities being executed at such time, or that include language similar to that contained in Section 5.07 (Effect of Benchmark Transition Event), are being executed or amended, as applicable, to incorporate or adopt a new benchmark interest rate to replace LIBOR, and

(2) (i) the election by the Credit Facility Agent or (ii) the election by the Required Lenders, in each case, with the consent of the Borrower (not to be unreasonably withheld, conditioned or delayed), to declare that an Early Opt-in Election has occurred and the provision, as applicable, by the Credit Facility Agent of written notice of such election to the Borrower and the Lenders or by the Required Lenders of written notice of such election to the Credit Facility Agent.

Eligible Assignee” means (a) an existing Lender, (b) any Affiliate of a Lender, (c) any Approved Fund with respect to a Lender or (d) any commercial bank, insurance company, investment or mutual fund or other entity that is an “accredited investor” (as defined in Regulation D under the Securities Act) and which extends credit or buys loans (excluding in each such case any Disqualified Institution or any Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof); provided that for any assignment, novation or transfer during the Term Loan Availability Period (or in the event of an assignment of a Working Capital Commitment, the Working Capital Availability Period) made in reliance on clause (b) or (c) above, such Lender or its rated Affiliate shall have agreed in writing with the Borrower to remain obligated to promptly fund any duly requested disbursement of the Commitment assigned, novated or transferred to such assignee or transferee (or any part thereof) should such assignee or transferee default in its obligation to fund any portion of the Commitment assigned or transferred to it.

 

6


Federal Funds Effective Rate” means, for any day, the weighted average (rounded upwards, if necessary, to the nearest 1/100 of 1%) of the rates on overnight federal funds transactions with members of the Federal Reserve System, as published on the next succeeding

Business Day by the Federal Reserve Bank of New York, or, if such rate is not so published for any day that is a Business Day, the average (rounded upwards, if necessary, to the next 1/100 of 1%) of the quotations for such day for such transactions received by the Intercreditor Agent from three federal funds brokers of recognized standing selected by it.

Federal Reserve Bank of New York’s Website” means the website of the Federal Reserve Bank of New York at http://www.newyorkfed.org, or any successor source.

Fees” means, collectively, each of the fees payable by the Borrower for the account of any Lender, any Issuing Bank or the Credit Facility Agent pursuant to Section 4.15 (Fees).

Final Maturity Date” means August 19, 2026.

First Repayment Date” has the meaning provided in Section 4.01(b) (Repayment of Term Loans).

Fronted Letter of Credit” means a Letter of Credit other than a Non-Fronted Letter of Credit.

Fronting Exposure” means, at any time there is a Defaulting Lender, with respect to any Issuing Bank, such Defaulting Lender’s pro rata share of outstanding LC Exposure with respect to Letters of Credit issued by such Issuing Bank, other than LC Exposure as to which such Defaulting Lender’s participation obligation has been reallocated to other Working Capital Lenders or cash collateralized in accordance with the terms hereof.

Fronting Fee” has the meaning provided in Section 4.15(d) (Fees).

Fronting Limit” means, at any time, with respect to any Issuing Bank, the amount set forth opposite the name of such Issuing Bank in the column entitled “Fronting Limit” on Schedule II (Issuing Bank Limits), or, in the case of any Working Capital Lender that becomes an Issuing Bank hereunder pursuant to Section 3.05 (Resignation as an Issuing Bank) or otherwise, such amount as set forth in the agreement evidencing the appointment of such Working Capital Lender as an Issuing Bank.

Guarantee” means the guarantee issued pursuant to the Common Security and Account Agreement by the Guarantor. The terms “Guarantee” and “Guaranteed” used as verbs shall have correlative meanings.

Incremental Amendment” has the meaning given in Section 2.09(c) (Incremental Commitments).

Incremental Lender/Issuing Bank” has the meaning given in Section 2.09(b) (Incremental Commitments).

Initial Coordinating Lead Arranger” means Banco Santander, S.A., New York Branch, Bank of America, N.A., The Bank of Nova Scotia, Houston Branch, Goldman Sachs Bank USA, ING Capital LLC, JPMorgan Chase Bank, N.A., Mizuho Bank, Ltd., Morgan Stanley Senior Funding, Inc., Natixis, New York Branch, Nomura Securities International, Inc., Royal Bank of Canada and Sumitomo Mitsui Banking Corporation, in each case, not in its individual capacity, but as initial coordinating lead arranger hereunder.

 

7


Intercompany Loan Agreement” has the meaning provided in the recitals.

Interest Payment Date” has the meaning provided in Section 4.04(a) (Interest Payment Dates).

Interest Period” means, with respect to any LIBOR Loan, the period beginning on the date on which such LIBOR Loan is made pursuant to Section 2.06(a) (Funding) or on the last day of the immediately preceding Interest Period therefor, as applicable, and ending on the numerically corresponding day in the calendar month that is one (1), two (2), three (3) or six (6) months thereafter (or, if available to all applicable Lenders, nine (9) or twelve (12) months), in each case as the Borrower may select in the relevant Disbursement Request or Interest Period Notice; provided, however, that (i) the Interest Period for any Advance shall commence on the date of the Advance (or the date of the conversion of any Base Rate Loans to LIBOR Loans in accordance with this Agreement) and shall extend up to (but not include) the first Interest Payment Date following the date of the Advance, (ii) if such Interest Period would otherwise end on a day that is not a Business Day, such Interest Period shall end on the next following Business Day (unless such next following Business Day is in a different calendar month, in which case such Interest Period shall end on the immediately preceding Business Day), (iii) any Interest Period that begins on the last Business Day of a month (or on a day for which there is no numerically corresponding day in the month at the end of such Interest Period) shall end on the last Business Day of the month at the end of such Interest Period, (iv) no Interest Period may end later than the Final Maturity Date, and (v) any Interest Period for a Loan which would otherwise end after the Final Maturity Date shall end on the Final Maturity Date.

Interest Period Notice” means a notice in substantially the form attached hereto as Exhibit F (Form of Interest Period Notice), executed by an Authorized Officer of the Borrower or, in the case of an Advance, a Disbursement Request.

ISP98” has the meaning given in Section 3.01(g) (Letters of Credit).

Issuing Bank” means each Working Capital Lender identified as an “Issuing Bank” on Schedule II (Issuing Bank Limits) and any other Working Capital Lender designated by the Borrower after the date hereof that has, or whose credit support provider has, a credit rating of A3 or higher by Moody’s, A- or higher by S&P or an equivalent rating by another nationally-recognized credit rating agency, and that has agreed in writing in its sole discretion to accept such designation as an Issuing Bank and to be bound by all of the terms contained in this Agreement and the other Finance Documents binding on an Issuing Bank in such capacity (provided that, a copy of such agreement has been delivered to the Credit Facility Agent), it being understood that such agreement may contain additional conditions to, or limitations on, such Issuing Bank’s obligation to issue Letters of Credit hereunder (including limits on the aggregate stated amount of Letters of Credit at any one time outstanding that may be issued by such Issuing Bank), and any such conditions or limitations are hereby incorporated by reference into this Agreement to the same extent and with the same force as if fully set forth herein. Each reference to an Issuing Bank contained in this Agreement and the other Finance Documents shall

 

8


be deemed to refer to the applicable Working Capital Lender solely in its capacity as the issuer of Letters of Credit hereunder and not in its capacity as a Working Capital Lender, and each reference to a Working Capital Lender contained in this Agreement and the other Finance Documents shall be deemed to refer to such Working Capital Lender in its capacity as such and not in its capacity (if applicable) as an Issuing Bank.

Issuing Bank Limit” means the limitation on the obligation of each Issuing Bank to issue Letters of Credit as identified in the column “Issuing Bank Limit” on Schedule II (Issuing Bank Limits) with respect to each Issuing bank.

LC Available Amount” means, for any Letter of Credit on any date of determination, the maximum amount available to be drawn under such Letter of Credit at any time on or after such date (assuming the satisfaction of all conditions for drawing enumerated therein).

LC Cash Collateral Account” means, an interest-bearing cash collateral account established upon the occurrence of a Loan Facility Event of Default by the Credit Facility Agent in its name for the benefit of the Working Capital Lenders and Issuing Banks, subject to the terms of this Agreement and the Common Security and Account Agreement.

LC Exposure” means, as of any time of determination and with respect to any Issuing Bank, the sum of (a) the aggregate undrawn amount of the outstanding Letters of Credit issued by such Issuing Bank at such time plus (b) the aggregate amount of all LC Loans made by such Issuing Bank and in which no other Working Capital Lender is required to participate that have not yet been repaid at such time plus (c) the aggregate amount of LC Reimbursement Payments that the Borrower has not yet repaid and have not yet been converted to LC Loans as of such time.

LC Fee” has the meaning provided in Section 4.15(c) (Fees).

LC Loan” means a loan by a Working Capital Lender to the Borrower deemed made pursuant to Section 3.02(c) and Section 3.02(f) (Reimbursement to Issuing Banks).

LC Payment Notice” has the meaning provided in Section 3.02(a) (Reimbursement to Issuing Banks).

LC Reimbursement Payment” has the meaning provided in Section 3.02(b) (Reimbursement to Issuing Banks).

Lender” means, as context requires, a Term Lender, a Working Capital Lender, or both.

Lender Assignment Agreement” means a Lender Assignment Agreement, substantially in the form of Exhibit G (Form of Lender Assignment Agreement).

Letter of Credit” means a standby letter of credit substantially in a form attached hereto as (i) Exhibit E-1 (Form of Letter of Credit – TETCO), if such letter of credit is to be issued to the counterparty under the agreement described in clause (a) of the definition of “Gas Transportation Agreements” in the Common Terms Agreement, (ii) Exhibit E-2 (Form of Letter of Credit – ANR), if such letter of credit is to be issued to the counterparty under the agreement

 

9


described in clause (b) of the definition of “Gas Transportation Agreements” in the Common Terms Agreement (which forms are acceptable to the Issuing Banks), (iii) Exhibit E-3 (Form of Letter of Credit – EnLink), if such letter of credit is to be issued to one of the counterparties under the agreement described in clause (c) of the definition of “Gas Transportation Agreements” in the Common Terms Agreement or (iv) such form as is otherwise reasonably acceptable to the Issuing Bank issuing such letter of credit, in each case issued pursuant to Section 3.01 (Letters of Credit) and in accordance with the policies and procedures of such Issuing Bank.

LIBOR” means, in respect of any Loan, if applicable, and in relation to any Relevant Interest Period, the percentage rate per annum as determined by the Credit Facility Agent to be equal to:

 

  (a)

the offered rate per annum for deposits in US Dollars which is quoted on the Screen Rate for the purpose of displaying London interbank offered rates of major banks for deposits in US Dollars as administered by ICE Benchmark Administration Limited (or any other Person which takes over the administration of that rate) in US Dollars, (before any correction, recalculation or republication by the administration) for a period of six months or such other period that corresponds to the Relevant Interest Period, at approximately 11:00 a.m. London time on the date that is two (2) Business Days prior to the first day of the Relevant Interest Period; or

 

  (b)

if no such quotation so appears, and no other page is so agreed between the Borrower and the Intercreditor Agent at or about such time, the arithmetic mean (rounded upwards, if necessary, to five decimal places) of the rates per annum for deposits in US Dollars for a period of six months or such other period that corresponds to the Relevant Interest Period (in each case as supplied to the Intercreditor Agent at its request), at which rates at least three of the Reference Banks were offering to leading banks in the London interbank market, or as otherwise defined in the this Agreement;

provided, in each case, that if any such rate is below zero, LIBOR will be deemed to be zero.

LIBOR Loan” means any Loan bearing interest at a rate determined by reference to LIBOR and the provisions of Article II (Commitments and Advances) and Article IV (Repayments, Prepayments, Interest and Fees).

Loan” means, as context requires, a Term Loan, a Working Capital Loan, an LC Loan or each of the foregoing.

Loan Obligations” means, collectively, all Senior Debt Obligations arising under the Credit Facility Agreement.

Maximum Rate” has the meaning provided in Section 11.08 (Interest Rate Limitation).

 

10


Non-Consenting Lender” means in respect of a Lender, if such Lender has failed to consent to a proposed amendment, waiver, consent or termination which pursuant to the terms of Section 11.01 (Decisions, Amendments, Etc.) requires the consent of all of the Lenders or all affected Lenders and with respect to which Lenders representing at least 50% of the sum of (i) the aggregate undisbursed Commitments plus (ii) the then aggregate outstanding principal amount of the Loans (excluding in each such case any Lender that is a Defaulting Lender or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, a Collateral Party, the Sponsor or any of Sponsor’s Affiliates, and each Commitment and any outstanding principal amount of any Loan of any such Term Lender) or Lenders affected by such proposed amendment, waiver, consent or termination, as the case may be, shall have granted their consent.

Non-Defaulting Lender” means, at any time, a Lender that is not a Defaulting Lender.

Non-Fronted LC Amount” has the meaning provided in Section 3.01(f) (Letters of Credit).

Non-Fronted Letter of Credit” means a Letter of Credit identified by the Borrower as such in the Request for Issuance.

Non-Fronting Limit” means, at any time, with respect to any Issuing Bank, the amount set forth opposite the name of such Issuing Bank in the column entitled “Non-Fronting Limit” on Schedule II (Issuing Bank Limits), or, in the case of any Working Capital Lender that becomes an Issuing Bank hereunder pursuant to Section 3.05 (Resignation as an Issuing Bank) or otherwise, such amount as set forth in the agreement evidencing the appointment of such Working Capital Lender as an Issuing Bank, as the same may be (a) reduced from time to time in accordance with Section 2.07 (Termination or Reduction of Commitments), (b) increased from time to time in accordance with Section 2.09 (Incremental Commitments), and (c) reduced or increased from time to time pursuant to assignments by or to such Lender pursuant to Section 11.04 (Assignments).

Note” means, as context requires, a Term Loan Note or a Working Capital Loan Note.

Pre-Completion Working Capital Loan Sublimit” means $100,000,000.

Reference Banks” means the principal London offices of each of Lloyds TSB Bank plc, JP Morgan Chase and HSBC Bank, or any other bank or financial institution as shall be specified by the Credit Facility Agent and approved by the Borrower (such approval not to be unreasonably withheld).

Register” has the meaning provided in Section 2.06(e) (Funding).

Related Parties” means, with respect to any specified Person, such Person’s Affiliates and the respective shareholders, members, partners, directors, officers, employees, agents, trustees, advisors and representatives of such Person and such Person’s Affiliates.

 

11


Relevant Governmental Body means the Federal Reserve Board and/or the Federal Reserve Bank of New York, or a committee officially endorsed or convened by the Federal Reserve Board and/or the Federal Reserve Bank of New York or any successor thereto.

Request for Issuance” has the meaning provided in Section 3.01(a) (Letters of Credit).

Required Lenders” means at any time, the Lenders holding in excess of 50.00% of the sum of (a) the aggregate undisbursed Commitments plus (b) the then aggregate outstanding principal amount of the Loans (excluding in each such case any Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, an Affiliated Lender, and each Commitment and any outstanding principal amount of any Loan of any such Lender). Such percentage shall be calculated by dividing the number of votes cast in favor of a Decision by the total number of votes cast with respect to such Decision.

Required Term Lenders” means at any time, the Term Lenders holding in excess of 50.00% of the sum of (a) the aggregate undisbursed Term Loan Commitments plus (b) the then aggregate outstanding principal amount of the Term Loans (excluding in each such case any Term Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, a Collateral Party, the Sponsor or any of Sponsor’s Affiliates, and each Term Loan Commitment and any outstanding principal amount of any Term Loan of any such Term Lender). Such percentage shall be calculated by dividing the number of votes cast in favor of a Decision by the total number of votes cast with respect to such Decision.

Required Working Capital Lenders” means at any time, the Working Capital Lenders holding in excess of 50.00% of the sum of (a) the aggregate undisbursed Working Capital Commitments plus (b) the then-aggregate outstanding principal amount of the Working Capital Loans (excluding in each such case any Working Capital Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, a Collateral Party, the Sponsor or any of the Sponsor’s Affiliates, and each Working Capital Commitment and any outstanding principal amount of any Working Capital Loan of any such Working Capital Lender). Such percentage shall be calculated by dividing the number of votes cast in favor of a Decision by the total number of votes cast with respect to such Decision.

Screen Rate” means Bloomberg Page LIBOR01 (or if such page is not accessible or ceases to display, such other page on the Bloomberg Screen or on the relevant pages of such other service as may be selected by the Intercreditor Agent for purposes of displaying comparable rates).

SOFR” with respect to any day means the secured overnight financing rate published for such day by the Federal Reserve Bank of New York, as the administrator of the benchmark, (or a successor administrator) on the Federal Reserve Bank of New York’s Website.

 

12


Term Lenders” means those Term Lenders identified on Schedule I (Lenders, Commitments) and each other Person that acquires the rights and obligations of any such Term Lender in accordance with Section 11.04 (Assignments) but excluding any Person that has assigned all of its rights and obligations under the Credit Facility Agreement in accordance with Section 11.04 (Assignments) (other than in connection with the sale of participations) and Participants.

Term Loan” means, with respect to each Term Lender, each advance to the Borrower of such Term Lender’s pro rata share of the Term Loan Commitment as the Borrower may request under Section 2.02 (Term Loan Availability) and the applicable Disbursement Request.

Term Loan Advance” means each Advance of Term Loans by the Term Lenders (or the Credit Facility Agent on their behalf) on any single date to the Borrower in accordance with Section 2.06 (Funding) and Article VII (Conditions Precedent).

Term Loan Availability Period” has the meaning provided in Section 2.02 (Term Loan Availability).

Term Loan Commitment” means the Base Term Loan Commitment and/or the Contingency Reserve Term Loan Commitment, as the case may be, and “Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

Term Loan Commitment Fee” has the meaning provided in Section 4.15(a) (Fees).

Term Loan Notes” means the promissory notes of the Borrower, substantially in the form of Exhibit B-1 (Form of Term Loan Note) evidencing Term Loans, in each case duly executed and delivered by an Authorized Officer of the Borrower in favor of each Term Lender that requests a Term Loan Note, including any promissory notes issued by the Borrower in connection with assignments of any Term Loan of the Term Lenders.

Term SOFR means the forward-looking term rate based on SOFR that has been selected or recommended by the Relevant Governmental Body.

Trade Date” has the meaning provided in Section 11.04(b) (Assignments).

Type” means, when used in reference to:

(a) any Loan or Advance, or the Loans constituting such Advance, Term Loans and/or Working Capital Loans (or any Type thereof) as the context requires; and

(b) any Commitment, a Term Loan Commitment and/or a Working Capital Commitment as the context requires.

UCP 600” has the meaning provided in Section 3.01(g)(iii) (Letters of Credit).

Unadjusted Benchmark Replacement” means the Benchmark Replacement excluding the Benchmark Replacement Adjustment.

 

13


Undisclosed Administration” means, in relation to a Lender or its direct or indirect parent company, the appointment of an administrator, provisional liquidator, conservator, receiver, trustee, custodian, or other similar official by a supervisory authority or regulator under or based on the law in the country where such Lender or such parent company is subject to home jurisdiction supervision, if applicable law requires that such appointment not be publicly disclosed.

Working Capital Advance” means each Advance of Working Capital Loans by or on behalf of the Working Capital Lenders on any single date to the Borrower in accordance with Section 2.06 (Funding) and Article VII (Conditions Precedent).

Working Capital Availability Period” means the Closing Date until the Working Capital Loan Termination Date.

Working Capital Commitment” means, with respect to each Working Capital Lender, the commitment of such Working Capital Lender to (i) make Working Capital Loans and (ii) make LC Loans in respect of Fronted Letters of Credit and Non-Fronted Letters of Credit (subject to such Working Capital Lender’s Non-Fronting Limit as set forth opposite the name of such Working Capital Lender in the column entitled “Non-Fronting Limit” on Schedule II (Issuing Bank Limits)), in an aggregate amount not to exceed the amount set forth opposite the name of such Working Capital Lender in the column entitled “Total Working Capital Commitment” in Schedule I (Lenders, Commitments), or if such Working Capital Lender has entered into one or more Lender Assignment Agreements, set forth opposite the name of such Working Capital Lender in the Register maintained by the Credit Facility Agent as such Working Capital Lender’s commitment, as the same may be (a) reduced from time to time in accordance with Section 2.07 (Termination or Reduction of Commitments), (b) increased from time to time in accordance with Section 2.09 (Incremental Commitments), (c) reduced or increased from time to time pursuant to assignments by or to such Working Capital Lender pursuant to Section 11.04 (Assignments) and (d) utilized, as of the applicable date of determination, in the amount of such Working Capital Lender’s Working Capital Commitment Exposure.

Working Capital Commitment Fee” has the meaning provided in Section 4.15(b) (Fees).

Working Capital Commitment Increase” has the meaning provided in Section 2.09(a) (Incremental Commitments).

Working Capital Commitment Increase Notice” has the meaning provided in Section 2.09(a) (Incremental Commitments).

Working Capital Commitment Exposure” means as of any time of determination and with respect to each Working Capital Lender, the sum of (i) the principal amount of its Working Capital Loans outstanding, plus (ii) the principal amount of its LC Loans outstanding, plus (iii) in the case of each Working Capital Lender that is an Issuing Bank, the aggregate undrawn amount of the outstanding Letters of Credit issued by it (excluding the aggregate amount thereof in respect of which other Working Capital Lenders are required to participate), plus (iv) aggregate LC Reimbursement Payments that have not yet converted to LC Loans under the outstanding Letters of Credit issued by it (excluding the aggregate amount thereof in respect of which other Working Capital Lenders are required to participate) plus (v) the aggregate amount of such Working Capital Lender’s participations in Letters of Credit issued by other Issuing Banks.

 

14


Working Capital Facility” has the meaning provided in the preamble.

Working Capital Lender Payment Notice” has the meaning provided in Section 3.02(c) (Reimbursement to Issuing Banks).

Working Capital Lenders” means those Working Capital Lenders identified on Schedule I (Lenders, Commitments) and each other Person that acquires the rights and obligations of any such Working Capital Lender in accordance with Section 11.04 (Assignments) but excluding any Person that has assigned all of its rights and obligations under the Credit Facility Agreement in accordance with Section 11.04 (Assignments) (other than in connection with the sale of participations) and Participants.

Working Capital Loan” has the meaning provided in Section 2.04(a) (Working Capital Loan Availability).

Working Capital Loan Availability Period” has the meaning provided in Section 2.04(a) (Working Capital Loan Availability).

Working Capital Loan Availability Date” means the date, no earlier than the date that is thirty (30) days prior to the date on which the Borrower reasonably anticipates that the LPS1 Substantial Completion Date (as defined in the EPC Contract) will occur, as certified in writing by the Borrower to the Credit Facility Agent (and confirmed in writing by the Independent Engineer).

Working Capital Loan Note” means the promissory notes of the Borrower, substantially in the form of Exhibit B-2 (Form of Working Capital Note) evidencing Working Capital Loans, in each case duly executed and delivered by an Authorized Officer of the Borrower in favor of each Working Capital Lender that requests a Working Capital Loan Note, including any promissory notes issued by the Borrower in connection with assignments of any Working Capital Loan of the Working Capital Lenders.

Working Capital Loan Termination Date” has the meaning provided in Section 2.04(a) (Working Capital Loan Availability).

 

15


EXHIBIT B-1 TO

CREDIT FACILITY AGREEMENT

Form Of Term Loan Note

[Omitted]


EXHIBIT B-2 TO

CREDIT FACILITY AGREEMENT

Form Of Working Capital Loan Note

[Omitted]


EXHIBIT C TO

CREDIT FACILITY AGREEMENT

[Reserved]

 

1


EXHIBIT D TO

CREDIT FACILITY AGREEMENT

[Reserved]

 

1


EXHIBIT E-1 TO

CREDIT FACILITY AGREEMENT

Form Of Letter of Credit – TETCO

[Omitted]


EXHIBIT E-2 TO

CREDIT FACILITY AGREEMENT

Form Of Letter of Credit – ANR

[Omitted]


EXHIBIT E-3 TO

CREDIT FACILITY AGREEMENT

Form Of Letter of Credit – EnLink

[Omitted]


EXHIBIT F TO

CREDIT FACILITY AGREEMENT

Form Of Interest Period Notice

[Omitted]


EXHIBIT G TO

CREDIT FACILITY AGREEMENT

Form Of Lender Assignment Agreement

[Omitted]

Exhibit 10.73

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

COMMON TERMS AGREEMENT

FOR THE LOANS

among

 

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as Borrower,

 

 

TRANSCAMERON PIPELINE, LLC,

as Guarantor,

 

 

NATIXIS, NEW YORK BRANCH,

as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties,

Each other Facility Agent that is Party hereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement

and

MIZUHO BANK, LTD.,

as Intercreditor Agent for the Facility Lenders

 

 

Dated as of August 19, 2019


CONTENTS

 

              Page  
1.  

DEFINITIONS AND INTERPRETATION

     1  
2.  

GENERAL PRINCIPLES OF THE LOANS

     1  
 

2.1

   Purpose and Scope of the Loans      1  
 

2.2

   Sequence of Advances of Senior Debt      2  
 

2.3

   Disbursement Procedures      2  
 

2.4

   Pro Rata Advances      3  
 

2.5

   Interest      4  
 

2.6

   Currency      4  
 

2.7

   Acknowledgement and Consent to Bail-In of EEA Financial Institutions      4  
 

2.8

   Acknowledgement Regarding Any Supported QFCs      5  
3.  

REPAYMENT, PREPAYMENT AND CANCELLATION

     6  
 

3.1

   CTA Payment Dates      6  
 

3.2

   Right of Repayment and Cancellation in Relation to a Single Facility Lender      7  
 

3.3

   No Repayments or Prepayments      8  
 

3.4

   Mandatory Prepayments      8  
 

3.5

   Voluntary Prepayments      12  
 

3.6

   Prepayment Fees and Breakage Costs      13  
 

3.7

   Pro Rata Payment      13  
 

3.8

   Reductions and Cancellations of Facility Debt Commitments      15  
 

3.9

   Late Payments      16  
 

3.10

   No Borrowing or Reinstatement      16  
4.  

CONDITIONS PRECEDENT

     16  
 

4.1

   Conditions to Closing Date and Initial Advance      16  
 

4.2

   Conditions to Each Advance      26  
 

4.3

   Conditions to Each Advance under the Working Capital Facility      29  
 

4.4

   Satisfaction of Conditions      30  
5.  

REPRESENTATIONS AND WARRANTIES OF THE OBLIGORS

     31  
 

5.1

   Initial Representations and Warranties of the Obligors      31  
 

5.2

   Repeated Representations and Warranties of the Obligors      40  
6.  

INCURRENCE OF ADDITIONAL SENIOR DEBT

     48  
 

6.1

   Permitted Senior Debt      48  
 

6.2

   Working Capital Debt      48  

 

-i-

Calcasieu Pass - Common Terms Agreement


 

6.3

   Replacement Senior Debt      50  
7.  

PERMITTED DEVELOPMENT EXPENDITURES/EXPANSIONS

     52  
 

7.1

   Permitted Development Expenditures      52  
 

7.2

   Expansion Contracts      53  
8.  

LNG SPA COVENANTS

     53  
 

8.1

   LNG SPA Maintenance      53  
 

8.2

   LNG SPA Mandatory Prepayment      55  
 

8.3

   Amendment of LNG SPAs      58  
 

8.4

   Sale of Supplemental Quantity      59  
 

8.5

   Sale of Pre-Commercial Quantities      60  
 

8.6

   Payment of LNG Sales Proceeds      60  
9.  

MATERIAL CONSTRUCTION CONTRACTS

     61  
 

9.1

   Change Orders      61  
 

9.2

   UOP Pre-Treatment Systems      62  
10.  

REPORTING BY THE BORROWER

     63  
 

10.1

   Accounting, Financial and Other Information      63  
 

10.2

   Quarterly Historical DSCR Certificate      64  
 

10.3

   Notices      64  
 

10.4

   Construction Reports      66  
 

10.5

   Operating Budget      69  
 

10.6

   Operating Statements and Reports      70  
 

10.7

   Insurance Reporting      71  
 

10.8

   Copies of Finance Documents      73  
 

10.9

   Construction Budget and Schedule      73  
11.  

RESTRICTED PAYMENTS

     74  
 

11.1

   Conditions to Restricted Payments      74  
 

11.2

   Certain Restricted Payments      75  
12.  

OBLIGOR COVENANTS

     75  
 

12.1

   Use of Proceeds      75  
 

12.2

   Maintenance of Existence, Franchises, Etc.      75  
 

12.3

   Project Construction; Maintenance of Properties      76  
 

12.4

   Books and Records; Inspection Rights      78  
 

12.5

   Material Project Agreements      78  
 

12.6

   Compliance with Law      82  
 

12.7

   Environmental Compliance      84  

 

-ii-

Calcasieu Pass - Common Terms Agreement


 

12.8

   Permits      84  
 

12.9

   Export Authorizations      85  
 

12.10

   FERC Order      85  
 

12.11

   Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages      85  
 

12.12

   Inspection Rights      86  
 

12.13

   Taxes      86  
 

12.14

   Limitation on Indebtedness      86  
 

12.15

   Guarantees      88  
 

12.16

   Limitation on Liens      88  
 

12.17

   Sale of Project Property      88  
 

12.18

   Merger, Division, Liquidation and Sale of All Assets      89  
 

12.19

   Limitation on Investments and Loans      89  
 

12.20

   Nature of Business      90  
 

12.21

   Transactions with Affiliates      90  
 

12.22

   Hedging Arrangements      91  
 

12.23

   Accounts      92  
 

12.24

   Separateness      92  
 

12.25

   Historical DSCR      94  
 

12.26

   Auditors      95  
 

12.27

   Gas Transportation Arrangements; Gas Purchase Arrangements      95  
 

12.28

   Insurance Covenant      95  
 

12.29

   Certain Real Property Rights; Real Property Documents; Leases      96  
 

12.30

   Margin Regulation      97  
 

12.31

   Further Assurances      97  
 

12.32

   As-Built Survey      98  
 

12.33

   ERISA      98  
13.  

CONSULTANTS

     98  
 

13.1

   Appointment of Consultants      98  
 

13.2

   Replacement and Fees      98  
 

13.3

   Access      99  
14.  

CONDITIONS TO COMPLETION; PROJECT COMPLETION DATE WATERFALL

     100  
 

14.1

   Conditions to Occurrence of the Project Completion Date      100  
 

14.2

   Project Completion Date Waterfall      104  
15.  

LOAN FACILITY EVENTS OF DEFAULT

     106  
 

15.1

   Loan Facility Events of Default      106  
 

15.2

   Declaration of Loan Facility Declared Default      112  
 

15.3

   Cessation of Loan Facility Declared Default      112  
 

15.4

   Instruction to Intercreditor Agent      112  

 

-iii-

Calcasieu Pass - Common Terms Agreement


16.  

COMMON REMEDIES AND ENFORCEMENT

     113  
 

16.1

   Facility Lender Remedies for Loan Facility Declared Events of Default      113  
 

16.2

   Remedies for Events of Default under Facility Agreements      114  
 

16.3

   Permitted Actions under Common Security and Account Agreement      114  
17.  

INTERCREDITOR ARRANGEMENTS

     114  
 

17.1

   Facility Agents; Facility Lender Action      114  
 

17.2

   Agreement to Comply with Intercreditor Agreement      115  
 

17.3

   Agreement Not to Amend Entrenched Intercreditor Provisions      115  
18.  

THE INTERCREDITOR AGENT

     117  
 

18.1

   Intercreditor Agreement      117  
 

18.2

   Relationship      117  
 

18.3

   Delivery of Documentation      117  
 

18.4

   Liability      117  
 

18.5

   Exoneration      118  
 

18.6

   Reliance      118  
 

18.7

   Resignation and Succession      118  
19.  

CHANGES TO THE PARTIES

     119  
 

19.1

   Represented Parties; Successors and Assigns      119  
 

19.2

   Transfers by the Obligors      119  
 

19.3

   Replacement of Facility Agents      119  
 

19.4

   Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement      120  
 

19.5

   Mitigation Obligations; Replacement of Lenders      122  
 

19.6

   Transfers by a Facility Lender      125  
 

19.7

   Register      125  
 

19.8

   Resulting Increased Costs      125  
20.  

SUBORDINATION

     126  
 

20.1

   Subordination      126  
21.  

TAX GROSS-UP AND INDEMNITIES

     126  
 

21.1

   Withholding Tax Gross-Up      126  
 

21.2

   Payment of Other Taxes      127  
 

21.3

   Indemnification by the Borrower      127  
 

21.4

   Indemnification by the Facility Lenders      127  
 

21.5

   Status of Facility Lenders and Facility Agents      128  
 

21.6

   Refunds      131  
 

21.7

   Evidence of Payments      131  

 

-iv-

Calcasieu Pass - Common Terms Agreement


 

21.8

   Survival      131  
 

21.9

   Defined Terms      132  
22.  

INCREASED COSTS

     132  
 

22.1

   Increased Costs      132  
 

22.2

   Relationship Between Increased Costs and Taxes      134  
23.  

MISCELLANEOUS

     134  
 

23.1

   Termination      134  
 

23.2

   Right of Set-Off      135  
 

23.3

   Waiver of Immunity      135  
 

23.4

   Expenses      136  
 

23.5

   Calculation of Floating Rate Obligations      137  
 

23.6

   Severability      137  
 

23.7

   Confidentiality      138  
 

23.8

   Notices      138  
 

23.9

   Successors and Assigns; Benefits of Agreement      141  
 

23.10

   Remedies      141  
 

23.11

   Execution in Counterparts      142  
 

23.12

   Governing Law      142  
 

23.13

   Waiver of Jury Trial      142  
 

23.14

   Consent to Jurisdiction      143  
 

23.15

   Amendments      143  
 

23.16

   Conflicts      144  
 

23.17

   Effectiveness      144  
 

23.18

   Limitations on Liability      145  
 

23.19

   Survival of Obligations      145  
 

23.20

   No Fiduciary Duty      145  
 

23.21

   USA Patriot Act Notice      146  
 

23.22

   Limited Recourse      146  
 

23.23

   Entire Agreement      148  

 

-v-

Calcasieu Pass - Common Terms Agreement


SCHEDULES

 

Schedule 5.1(f)(ii) Prior Locations

     5.1(f)(ii)-1  

Schedule 5.2(m) Real Property Interests

     5.2(m)-1  

Schedule A Common Definitions and Rules of Interpretation

     A-1  

Schedule B – 1 Disbursement Request Form (Term Loans)

     B-1  

Schedule B – 2 Disbursement Request Form (Working Capital Loans)

     B-2  

Schedule B – 3 Issuance Request Form (Letters of Credit)

     B-1  

Schedule C Table of Requirements for Legal Opinions – Conditions to Closing

     C-1  

Schedule D – 1 Construction Budget and Schedule – Construction Budget

     D-1  

Schedule D – 2 Construction Budget and Schedule – Construction Schedule

     D-2  

Schedule E Know Your Customer Documentation

     E-1  

Schedule F Material Permits

     F-1  

Schedule G Disclosure Schedule

     G-1  

Schedule H Material Project Agreements and Certain Other Contracts

     H-1  

Schedule I Change Orders

     I-1  

Schedule J Transactions With Affiliates

     J-1  

Schedule K Gas Sourcing Plan

     K-1  

Schedule L Schedule of Minimum Insurance

     L-1  

Schedule M Independent Insurance Experts

     M-1  

Schedule N Senior Creditors’ Advisors and Consultants

     N-1  

Schedule O Lenders’ Reliability Test Criteria

     O-1  

Schedule P – 1 Replacement Facility Agent Accession Agreement

     P-1  

Schedule P – 2 New Facility Agent Accession Agreement (Additional Senior Debt)

     P-2  

Schedule Q – 1 Addresses For Notices To Obligors

     Q-1  

Schedule Q – 2 Addresses For Notices To Facility Agents And Facility Lenders

     Q-2  

Schedule R Base Case Forecast

     R-1  

Schedule S – 1 Form of General Subordination Agreement

     S-1  

Schedule S – 2 Form of Obligor Subordination Agreement

     S-2  

Schedule T Knowledge Parties

     T-1  

Schedule U Real Property Documents

     U-1  

Schedule V Schedule of Certain Real Property Rights

     V-1  

 

-vi-

Calcasieu Pass - Common Terms Agreement


Schedule W Form of Disbursement Endorsement

     W-1  

Schedule X Phase I Environmental Assessments

     X-1  

Schedule Y Disqualified Institutions

     Y-1  

Schedule Z Survey Endorsements

     Z-1  

 

-vii-

Calcasieu Pass - Common Terms Agreement


COMMON TERMS AGREEMENT

FOR THE LOANS

This COMMON TERMS AGREEMENT FOR THE LOANS, dated as of August 19, 2019 (the “Common Terms Agreement” or this “Agreement”), is made among:

VENTURE GLOBAL CALCASIEU PASS, LLC, a limited liability company organized under the laws of the State of Delaware (the “Borrower”),

TRANSCAMERON PIPELINE, LLC, a limited liability company organized under the laws of the State of Delaware (the “Guarantor”),

NATIXIS, NEW YORK BRANCH, as the Facility Agent for the Credit Facility Lender Parties under the Credit Facility Agreement on behalf of itself and the Credit Facility Lender Parties (the “Credit Facility Agent”),

Each other Facility Agent that is Party hereto from time to time in accordance with this Agreement and the other Finance Documents on behalf of itself and the Facility Lenders under its Facility Agreement, and

MIZUHO BANK, LTD., as the intercreditor agent for the Facility Lenders on the terms and conditions set forth in the Intercreditor Agreement (in such capacity, the

Intercreditor Agent”).

 

1.

DEFINITIONS AND INTERPRETATION

 

  (a)

Except as otherwise expressly provided herein, capitalized terms used in this Agreement and its Schedules shall have the meanings assigned to them in Section 1.3 of Schedule A (Common Definitions and Rules of Interpretation Definitions).

 

  (b)

In this Agreement and the Schedules hereto, except as otherwise expressly provided herein, the interpretation provisions contained in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation – Interpretation) shall apply.

 

2.

GENERAL PRINCIPLES OF THE LOANS

 

  2.1

Purpose and Scope of the Loans

 

  (a)

The Borrower shall use the proceeds of the Initial Senior Debt solely in accordance with Section 12.1 (Use of Proceeds).

 

  (b)

The Borrower shall use the proceeds of any Senior Debt other than the Initial Senior Debt for the respective purposes specified in the relevant Facility Agreement or other applicable Senior Debt Instrument or Permitted Senior Debt Hedging Instrument pursuant to which such Senior Debt is incurred.

 

-1-

Calcasieu Pass - Common Terms Agreement


  (c)

No Facility Lender or Facility Agent or the Intercreditor Agent is bound to monitor or verify the application of any amount borrowed by the Borrower pursuant to this Agreement or any other Finance Document.

 

  2.2

Sequence of Advances of Senior Debt

 

  (a)

Subject to the satisfaction (or waiver) of the applicable conditions in Article 4 (Conditions Precedent) and during the Term Loan Availability Period and/or Working Capital Loan Availability Period, as applicable, Advances by the Credit Facility Lenders under the Credit Facility Agreement in respect of Term Loan Commitments shall be made (i) in respect of the Initial Advance, on the Closing Date and (ii) in respect of any other Advance, after utilization of all of the proceeds of the Closing Date Equity Funding and all of the proceeds of the Initial Advance.

 

  (b)

The sequencing of Advances under any Senior Debt (including Additional Senior Debt) other than Initial Senior Debt shall be as set forth in the Senior Debt Instrument for such Senior Debt.

 

  2.3

Disbursement Procedures

 

  (a)

All disbursements of Loans shall be made to the Borrower.

 

  (b)

Disbursements of Loans shall be requested by the Borrower in a duly completed Disbursement Request substantially in the form set forth in Schedule B-1 (Disbursement Request Form (Term Loans)), Schedule B-2 (Disbursement Request Form (Working Capital Loans)) or Schedule B-3 (Issuance Request Form (Letters of Credit)) (or in such other form as may be required pursuant to a Facility Agreement) and may be requested no more frequently than twice in any calendar month, except:

 

  (i)

as required for payment of interest and commitment fees during the Availability Period; or

 

  (ii)

as otherwise provided in the relevant Facility Agreement.

 

  (c)

The Borrower shall request disbursements of Loans by delivering to the Intercreditor Agent and each Facility Agent in respect of the Loans being requested a Disbursement Request in accordance with Section 2.4 (Pro Rata Advances) and the terms of the relevant Facility Agreement.

 

  (d)

Each Disbursement Request shall be irrevocable and the obligation of each Facility Lender to make an Advance of Loans under its Facility Agreement shall be subject to:

 

  (i)

with respect to the Initial Advance of the Term Loans and the issuance of any letters of credit under the Working Capital Facility

 

-2-

Calcasieu Pass - Common Terms Agreement


  required to be issued as of the Closing Date, the prior satisfaction or waiver of each of the common conditions precedent set forth in Section 4.1 (Conditions to Closing Date and Initial Advance) and Section 4.2 (Conditions to Each Advance);

 

  (ii)

with respect to any Advance of the Term Loans following the Initial Advance, the prior satisfaction or waiver of each of the common conditions precedent set forth in Section 4.2 (Conditions to Each Advance);

 

  (iii)

with respect to any Advance of the Working Capital Facility or issuance of letters of credit thereunder (other than the issuance of any letters of credit under the Working Capital Facility required to be issued as of the Closing Date), the prior satisfaction or waiver of each of the common conditions precedent set forth in Section 4.3 (Conditions to Each Advance under the Working Capital Facility); and

 

  (iv)

with respect to any Advance of Loans made under any other Facility Agreement, the prior satisfaction of each of the conditions precedent to such Advance set forth in such Facility Agreement.

 

  2.4

Pro Rata Advances

 

  (a)

Except with respect to (i) any Facility Debt Commitments that have been suspended pursuant to any Facility Agreement, (ii) Loans the proceeds of which are to be used for specified purposes, including Working Capital Debt, as specified in the applicable Facility Agreements and (iii) Advances to pay interest and commitment fees during the Availability Period under a respective Facility Agreement (which shall be borrowed pursuant to the terms of such respective Facility Agreement), the Borrower shall borrow concurrently under each of the Facility Agreements whose Facility Debt Commitments have not been fully borrowed or cancelled and shall borrow pro rata in the proportion that the unborrowed portion of each Facility Lender’s Facility Debt Commitment bears to the total of the unborrowed portion of the Senior Debt Commitments of all relevant Facility Lenders under the applicable Facility Agreements. If Advances cannot be made exactly pro rata due solely to minimum disbursement amounts and required integral multiples of disbursements under any Facility Agreement, Advances shall be made in amounts as near to such exactly proportionate amounts as possible, to the extent reasonably practicable and in a manner that is consistent, fair and equitable across affected Facility Agreements, and shall be deemed to be Advances in compliance with this Section 2.4 (Pro Rata Advances).

 

-3-

Calcasieu Pass - Common Terms Agreement


  (b)

The Borrower shall promptly notify the Intercreditor Agent (providing reasonably sufficient details) if funds are not received from any Facility Lender by the close of business on the next succeeding Business Day after the date on which any such disbursement is due to be received.

 

  2.5

Interest

Interest shall accrue on each Loan at the times and in the amounts specified in the relevant Facility Agreement.

 

  2.6

Currency

 

  (a)

The Borrower shall only submit a Disbursement Request denominated in whole US Dollars except in the case of:

 

  (i)

the final Advance under a Facility Agreement; and

 

  (ii)

any Advance, in whole or in part, in respect of the payment of interest or commitment fees.

 

  (b)

All Loans shall be stated, made and disbursed in US Dollars.

 

  (c)

The portion of any Advance comprising funds under any Facility Agreement shall not exceed the available Facility Debt Commitment under such Facility Agreement.

 

  (d)

The minimum quantum of any Advance under a Facility Agreement shall be as specified in such Facility Agreement.

 

  (e)

The Borrower shall make all payments of any amount with respect to the Loans (whether comprising fees, interest, principal, premium, if any, or Breakage Costs) in US Dollars.

 

  2.7

Acknowledgement and Consent to Bail-In of EEA Financial Institutions

Notwithstanding anything to the contrary in any Finance Document or in any other agreement, arrangement or understanding among any such parties, each party hereto acknowledges that any liability of any EEA Financial Institution arising under any Finance Document, to the extent such liability is unsecured, may be subject to the Write-Down and Conversion Powers of an EEA Resolution Authority and agrees and consents to, and acknowledges and agrees to be bound by:

 

  (a)

the application of any Write-Down and Conversion Powers by an EEA Resolution Authority to any such liabilities arising hereunder which may be payable to it by any party hereto that is an EEA Financial Institution; and

 

  (b)

the effects of any Bail-in Action on any such liability, including, if applicable:

 

-4-

Calcasieu Pass - Common Terms Agreement


  (i)

a reduction in full or in part or cancellation of any such liability;

 

  (ii)

a conversion of all, or a portion of, such liability into shares or other instruments of ownership in such EEA Financial Institution, its parent entity, or a bridge institution that may be issued to it or otherwise conferred on it, and that such shares or other instruments of ownership will be accepted by it in lieu of any rights with respect to any such liability under this Agreement or any other Finance Document; or

 

  (iii)

the variation of the terms of such liability in connection with the exercise of the Write-Down and Conversion Powers of any EEA Resolution Authority.

 

  2.8

Acknowledgement Regarding Any Supported QFCs

To the extent that the Finance Documents provide support, through a guarantee or otherwise, for Permitted Hedging Instruments or any other agreement or instrument that is a QFC (such support, “QFC Credit Support” and each such QFC a “Supported QFC”), the parties acknowledge and agree as follows with respect to the resolution power of the Federal Deposit Insurance Corporation under the Federal Deposit Insurance Act and Title II of the Dodd-Frank Wall Street Reform and Consumer Protection Act (together with the regulations promulgated thereunder, the “U.S. Special Resolution Regimes”) in respect of such Supported QFC and QFC Credit Support (with the provisions below applicable notwithstanding that the Finance Documents and any Supported QFC may in fact be stated to be governed by the laws of the State of New York and/or of the United States or any other state of the United States):

 

  (a)

In the event a Covered Entity that is party to a Supported QFC (each, a “Covered Party”) becomes subject to a proceeding under a U.S. Special Resolution Regime, the transfer of such Supported QFC and the benefit of such QFC Credit Support (and any interest and obligation in or under such Supported QFC and such QFC Credit Support, and any rights in property securing such Supported QFC or such QFC Credit Support) from such Covered Party will be effective to the same extent as the transfer would be effective under the U.S. Special Resolution Regime if the Supported QFC and such QFC Credit Support (and any such interest, obligation and rights in property) were governed by the laws of the United States or a state of the United States. In the event a Covered Party or a BHC Act Affiliate of a Covered Party becomes subject to a proceeding under a U.S. Special Resolution Regime, Default Rights under the Finance Documents that might otherwise apply to such Supported QFC or any QFC Credit Support that may be exercised against such Covered Party are permitted to be exercised to no greater extent than such Default Rights could be exercised under the U.S. Special Resolution Regime if the Supported QFC and the Finance Documents were governed by the laws of the United States or a

 

-5-

Calcasieu Pass - Common Terms Agreement


  state of the United States. Without limitation of the foregoing, it is understood and agreed that rights and remedies of the parties with respect to a Defaulting Lender shall in no event affect the rights of any Covered Party with respect to a Supported QFC or any QFC Credit Support.

 

  (b)

As used in this Section 2.8 (Acknowledgement Regarding Any Supported QFCs), the following terms have the following meanings:

 

  (i)

BHC Act Affiliate” of a party means an “affiliate” (as such term is defined under, and interpreted in accordance with, 12 U.S.C. 1841(k)) of such part.

 

  (ii)

Covered Entity” means any of the following:

 

  (A)

a “covered entity” as that term is defined in, and interpreted in accordance with, 12 C.F.R. §252.82(b);

 

  (B)

a “covered bank” as that term is defined in, and interpreted in accordance with, 12 C.F.R. §47.3(b); or

 

  (C)

a “covered FSI” as that term is defined in, and interpreted in accordance with, 12 C.F.R. §382.2(b).

 

  (iii)

Default Right” has the meaning assigned to that term in, and shall be interpreted in accordance with, 12 C.F.R. §§ 252.81, 47.2 or 382.1, as applicable.

 

  (iv)

QFC” has the meaning assigned to the term “qualified financial contract” in, and shall be interpreted in accordance with, 12 U.S.C. 5390(c)(8)(D).

 

3.

REPAYMENT, PREPAYMENT AND CANCELLATION

 

  3.1

CTA Payment Dates

 

  (a)

Subject to the relevant Facility Agreement, the Borrower shall pay the interest, and repay the principal on each Loan made available to it under each Facility Agreement in installments, which shall be payable on each CTA Payment Date up to and including the Final Maturity Date under such Facility Agreement.

 

  (b)

The Borrower shall ensure that any Senior Debt Instrument (other than any Indenture) provides that the dates for payment of principal under each such Senior Debt Instrument coincide with the Quarterly Payment Dates.

 

  (c)

The interest periods, date of first payment of interest and date of first repayment of principal in respect of Loans shall be as specified in the Facility Agreements.

 

-6-

Calcasieu Pass - Common Terms Agreement


  (d)

The amount of Senior Debt Obligations payable by the Borrower on any CTA Payment Date shall be calculated in accordance with the provisions of the Senior Debt Instrument or Permitted Senior Debt Hedging Instrument pursuant to which such Senior Debt was incurred as follows:

 

  (i)

in respect of principal payments, based on the Amortization Schedule or other principal repayment requirements applicable to the applicable Facility Agreement;

 

  (ii)

in respect of interest payments, in accordance with the provisions of the applicable Facility Agreement;

 

  (iii)

in respect of Permitted Senior Debt Hedging Liabilities, in accordance with the provisions of the applicable Permitted Senior Debt Hedging Instrument; and

 

  (iv)

in respect of all other Senior Debt Obligations, in accordance with the applicable Senior Debt Instrument and the Finance Documents.

 

  (e)

The Borrower shall repay on the Final Maturity Date set forth under each Facility Agreement the full amount of the Loans then outstanding under each such Facility Agreement.

 

  (f)

If any payment due under a Loan or any other amount owed to any Facility Lender falls due on a day which is not a “business day” under the terms of the applicable Facility Agreement, the due date for such payment shall be determined in accordance with the terms of such Facility Agreement, except in the case of the Final Maturity Date under a Facility Agreement, in which case the due date for such payment with respect to such Facility Agreement shall be the immediately preceding Business Day; provided, in each case, that if the due date for any payment under a Loan is extended or shortened as a result of such determination, such extended or shortened period, as the case may be, shall be used in the computation of the amount of interest owed on such extended or shortened due date.

 

  3.2

Right of Repayment and Cancellation in Relation to a Single Facility Lender

 

  (a)

Except as otherwise provided in the relevant Facility Agreement, if any of the circumstances in Section 19.5(c) (Mitigation Obligations; Replacement of Lenders) occurs (other than an Illegality Event, which is addressed under Section 3.4(a)(vi) (Mandatory Prepayments—Illegality)), the Borrower shall have the right (but not the obligation) to give the Intercreditor Agent and the relevant Facility Lender at least three Business Days’ written notice of its intention to cancel the Facility Debt Commitments and repay the Loans of the Facility Lender affected by the relevant circumstance.

 

-7-

Calcasieu Pass - Common Terms Agreement


  (b)

On receipt of a notice referred to in clause (a) above:

 

  (i)

the Facility Debt Commitment of such Facility Lender shall immediately be reduced to zero; and

 

  (ii)

the Borrower shall, subject to Section 3.5(c) (Voluntary Prepayments) repay (on a non-pro rata basis) all Senior Debt Obligations owed to such Facility Lender on the last day of the Relevant Interest Period which ends after the Borrower has given notice under clause (a) above (or, if earlier, the date specified by the Borrower in such notice or as required by law).

 

  (c)

Such repayment may be made with the proceeds of Replacement Senior Debt incurred in accordance with Section 6.3 (Replacement Senior Debt) or with other funds then available to the Borrower and permitted under the Finance Documents to be used for such purpose.

 

  3.3

No Repayments or Prepayments

No repayments or prepayments of any Loan may be made other than the repayments or prepayments expressly required or permitted by this Article 3 (Repayment, Prepayment and Cancellation) and, with respect to each Loan, the applicable Facility Agreement.

 

  3.4

Mandatory Prepayments

 

  (a)

Except in the following circumstances, no mandatory prepayments of the Loans are required to be made by the Borrower.

 

  (i)

Insurance and Condemnation Proceeds

The Borrower shall make any prepayments of the Loans required to be made with respect to certain Insurance Proceeds and Condemnation Proceeds in accordance with Section 5.2 (Insurance and Condemnation Proceeds) of the Common Security and Account Agreement.

 

  (ii)

Performance Liquidated Damages

Any Performance Liquidated Damages in excess of $10 million (in the aggregate across all Material Construction Contracts) that are paid to an Obligor pursuant to a Material Construction Contract shall be deposited into the Additional Proceeds Prepayment Account(s) and applied by the Borrower to make prepayments of the Loans, except to the extent such amounts are applied to:

 

-8-

Calcasieu Pass - Common Terms Agreement


  (A)

Complete or repair, the Project Facilities in respect of which the Performance Liquidated Damages were paid or to pay Project Costs in respect of the Project Facilities within 180 days following receipt thereof (or 270 days if a commitment to complete or repair such Project Facilities or to pay such Project Costs is entered into within 180 days following the receipt of such proceeds); or

 

  (B)

repay or reimburse providers of Equity Funding to the extent such Equity Funding was used to complete or repair the Project Facilities in respect of which the Performance Liquidated Damages were paid or to pay Project Costs in respect of the Project Facilities.

 

  (iii)

LNG SPA Payment Events

The Borrower shall make prepayments (if any) of Loans and cancel Senior Debt Commitments as may be required upon the occurrence of a LNG SPA Prepayment Event in accordance with Section 8.2 (LNG SPA Mandatory Prepayment).

 

  (iv)

Termination Payments

In the event that the Borrower receives any termination payments or proceeds in connection with the termination of any Material Project Agreement, such amounts shall be deposited into the Additional Proceeds Prepayment Account(s) to make prepayments of the Loans.

 

  (v)

Net Cash Proceeds from the Sale of Project Property

To the extent that Net Cash Proceeds received by an Obligor from the sale of Project Property (other than asset sales permitted under Section 12.17 (Sale of Project Property)), and those Net Cash Proceeds are not used to purchase replacement assets within 180 days following receipt thereof (or 270 days if a commitment to purchase replacement assets is entered into within 180 days following the receipt of such proceeds), the Borrower shall make prepayments of the Loans in the amount of those unused proceeds.

 

  (vi)

Illegality

Except as otherwise provided in a Facility Agreement in respect of Advances based on LIBOR, upon the Intercreditor Agent providing notice to the Borrower of an Illegality Event with respect to a Facility Lender (together with the related information about such illegality described in Section 19.5 (Mitigation Obligations;

 

-9-

Calcasieu Pass - Common Terms Agreement


Replacement of Lenders)), and subject to Section 19.5 (Mitigation Obligations; Replacement of Lenders):

 

  (A)

the Facility Debt Commitment of such Facility Lender shall be suspended until such date during the applicable Availability Period that such Facility Lender notifies its Facility Agent that the circumstances giving rise to such determination no longer exist, provided that if the Borrower notifies the affected Facility Lender and the Intercreditor Agent that it intends to exercise its rights under Section 19.5 (Mitigation Obligations; Replacement of Lenders) to require an assignment of the Facility Lender’s rights, interests and commitments as a result of the Illegality Event, the Facility Debt Commitments shall be transferred to the assignee Facility Lender and not suspended as set forth herein; and

 

  (B)

the Borrower shall repay any principal and interest outstanding in respect of such Facility Lender’s Loans on the earlier of:

 

  (1)

the next succeeding Quarterly Payment Date falling at least 60 days after the date on which the Intercreditor Agent has provided such notice to the Borrower; and

 

  (2)

the date (if any) required under applicable law.

For the avoidance of doubt, the Borrower may also require the Facility Lender to assign its rights, interests and obligations in accordance with Section 19.5 (Mitigation Obligations; Replacement of Lenders) upon the occurrence of an Illegality Event, which assignment shall extinguish the need for this mandatory prepayment if it occurs prior to the date such mandatory prepayment is required to have occurred.

 

  (vii)

Restricted Payments

Except if a Loan Facility Declared Default has occurred and is Continuing following the delivery of the notice provided under Section 4.6(b) (Control and Investment of Funds in Accounts) of the Common Security and Account Agreement (in which case the cash waterfall provided in Section 4.8 (Accounts During the Continuance of a Declared Event of Default) of the Common Security and Account Agreement shall apply), if, at any time after the end of the quarter in which the Project Completion Date occurs, the Borrower has not met the conditions to make a

 

-10-

Calcasieu Pass - Common Terms Agreement


Restricted Payment pursuant to Section 11.1 (Conditions to Restricted Payments) for four (4) consecutive quarters (other than as a result of a failure to meet the condition in Section 11.1(f) (Conditions to Restricted Payments), which is addressed instead by the mandatory prepayment in sub-clause (iii) (LNG SPA Payment Events) above), but solely to the extent such mandatory prepayment was in fact made in connection with such event, and for as long as such failure to meet such conditions is continuing, on each Quarterly Payment Date during such period the Borrower shall make a mandatory prepayment with the amount that would otherwise have been available for a Restricted Payment in accordance with Section 4.5(n)(ii) (Deposits and Withdrawals –Distribution Account) of the Common Security and Account Agreement less any amounts reasonably estimated to be due and payable at any higher level of the cash waterfall within the 30 days following such Quarterly Payment Date.

 

  (viii)

Letters of Credit

To the extent that the Senior Facilities Debt Service Reserve Account is funded with the proceeds of the Contingency Reserve Account on the Project Completion Date pursuant to Section 14.2(c)(ii)(D) (Project Completion Date Waterfall) and thereafter such amount is replaced by an Acceptable Debt Service Reserve LC, the Borrower shall make prepayments of the Term Loans in an amount equal to the lesser of (x) the face amount of the Acceptable Debt Service Reserve LC credited to the Senior Facilities Debt Service Reserve Account and (y) the amount of cash on deposit in the Senior Facilities Debt Service Reserve Account; provided that such amount shall not exceed the sum of (A) the aggregate amount transferred to the Senior Facilities Debt Service Reserve Account pursuant to Section 14.2(c)(ii)(D) (Project Completion Date Waterfall) and (B) the aggregate amount transferred from the Completion Reserve Account to the Senior Facilities Debt Service Reserve Account on the Project Completion Date; provided further that such amount shall not exceed the Senior Facilities Reserve Amount.

 

  (ix)

Contingency Reserve Amount

On the Project Completion Date, the Borrower shall make a prepayment of the Term Loans as specified in Section 14.2(c)(ii)(E) (Project Completion Date Waterfall).

 

-11-

Calcasieu Pass - Common Terms Agreement


  (x)

Replacement Debt

The Borrower shall use the proceeds of any Replacement Senior Debt to prepay or repay Senior Debt and/or replace all or part of the Facility Debt Commitments in accordance with Section 6.3 (Replacement Senior Debt).

 

  (b)

Mandatory prepayments to Facility Lenders will be made with accrued interest on the amount so prepaid, and upon not less than three (3) Business Days’ prior written notice to each Facility Agent.

 

  (c)

Except as provided in Section 3.7 (Pro Rata Payment), mandatory prepayments will be applied pro rata among each Senior Creditor Group under this Agreement (and in the case of outstanding Term Loans, pro rata) based on the Loans outstanding on the date of such prepayment.

 

  (d)

Except for a mandatory prepayment in accordance with sub-clause 3.4(a)(ii) (Mandatory Prepayments – Performance Liquidated Damages), 3.4(a)(viii) (Mandatory Prepayments – Letters of Credit) above and/or incurrence of Replacement Senior Debt pursuant to Section 6.3 (Replacement Senior Debt) below, which shall be applied pro rata against subsequent scheduled payments, all mandatory prepayments under this Section 3.4 (Mandatory Prepayments) shall be paid and applied in inverse order of maturity.

 

  3.5

Voluntary Prepayments

 

  (a)

Except as otherwise provided in any applicable Facility Agreement with respect to voluntary prepayments, the Borrower shall have the right, upon not less than three (3) Business Days’ prior written notice to the Intercreditor Agent and each Facility Agent, to make voluntary prepayments of Loans, in multiples of $1,000,000, either in whole or in part, at any time.

 

  (b)

Each notice of voluntary prepayment shall be irrevocable, except that a notice of voluntary prepayment may state that such notice is conditioned upon the effectiveness of other credit facilities or debt instruments in respect of Replacement Senior Debt, in which case such notice may be revoked by the Borrower (by written notice to the Intercreditor Agent and each Facility Agent on or prior to the specified effective date) if such condition is not satisfied. Within 30 days after the revocation of the notice of voluntary prepayment in accordance with the provisions of this clause (b), the Borrower shall pay any Breakage Costs incurred by any Facility Lender as a result of such notice and revocation.

 

  (c)

In the case of a partial voluntary prepayment, the Borrower may not make such voluntary prepayment with respect to Term Loans prior to the Project Completion Date unless it certifies to the Intercreditor Agent (and the Independent Engineer concurs with such certification in writing) that such

 

-12-

Calcasieu Pass - Common Terms Agreement


voluntary prepayment will not result in the Obligors’ having an insufficient amount of committed or funded capital to fund (on the basis of all other available funds, including funds in the Construction Account, remaining Facility Debt Commitments and/or the proceeds of any Replacement Senior Debt to be deposited into the Construction Account concurrently with such cancellation) the remaining expenditures required to achieve the Project Completion Date by, the Date Certain, in accordance with the Construction Budget and Schedule.

 

  (d)

Except as provided in Section 3.7 (Pro Rata Payment), voluntary prepayments will be applied pro rata among each Senior Creditor Group under this Agreement (and in the case of outstanding Term Loans, pro rata, except as otherwise provided in the Credit Facility Agreement) based on the Loans outstanding on the date of such prepayment and in inverse order of maturity.

 

  3.6

Prepayment Fees and Breakage Costs

Any prepayment (whether a mandatory prepayment or voluntary prepayment) of Loans or cancellation of Facility Debt Commitments, including prepayments or cancellations made in accordance with this Article 3 (Repayment, Prepayment and Cancellation), Section 6.3 (Replacement Senior Debt) or Section 19.5 (Mitigation Obligations; Replacement of Lenders) shall, in each case, be made without any prepayment charges, fees, premium, penalty or other charges other than (a) Breakage Costs incurred (if any are required to be paid pursuant to the terms of the applicable Facility Agreement) and (b) prepayment fees, premia, penalties or charges specified in any Facility Agreement, including for Working Capital Debt. Unless otherwise specified in an individual Facility Agreement, Breakage Costs (if any) with respect to any prepayment shall be payable only if such prepayment is made on a date other than a CTA Payment Date.

 

  3.7

Pro Rata Payment

Except as specified in Section 6.3(a)(viii) (Replacement Senior Debt) or to the extent that any Facility Lender waives or declines receipt of its Pro Rata Payment of any prepayment in accordance with the terms of any Senior Debt Instrument to which it is a party, at any time the Borrower makes a payment or prepayment in whole or in part of the Senior Debt Obligations owed to one or more Facility Lenders, the Borrower shall make a Pro Rata Payment to all other Facility Lenders (and in the case of outstanding Term Loans, pro rata); provided that:

 

  (a)

except as otherwise provided in any individual Facility Agreement, the mandatory prepayments described in Section 3.4(a)(vi) (Mandatory Prepayments – Illegality) will be applied pro rata only to the affected Loans and not pro rata to each Loan;

 

-13-

Calcasieu Pass - Common Terms Agreement


  (b)

(i) a voluntary prepayment of Loans made under the Credit Facility Agreement or any other Facility Agreement for Loans that are not Working Capital Debt may be made without a pro rata repayment of Loans under any Facility Agreement for Working Capital Debt (and, conversely, a voluntary prepayment of Loans under any Facility Agreement for Working Capital Debt may be made without a voluntary prepayment of Loans under any other Facility Agreement) and (ii) only the mandatory prepayments set forth in Section 3.4(a)(iii) (Mandatory Prepayments LNG SPA Payment Events) (but only to the extent set forth in, and subject to the requirements of, Section 8.2 (LNG SPA Mandatory Prepayment)) will be applied pro rata with respect to any Working Capital Debt; and

 

  (c)

the following prepayments will not be subject to the pro rata payment requirement:

 

  (i)

a voluntary or mandatory prepayment of Loans to Facility Lenders under a Facility Agreement, whose Loans thereunder have been amended and extended in accordance with its terms, to the extent such Facility Lenders have agreed to a non pro rata prepayment, in which case prepayments to such Facility Lenders shall be made on the basis set forth in the relevant Facility Agreement, as amended and extended, in accordance with the terms of such agreement;

 

  (ii)

a voluntary prepayment of Loans to only certain affected Facility Lenders or only Facility Lenders under certain affected Facility Agreements made pursuant to Section 3.2 (Right of Repayment and Cancellation in Relation to a Single Facility Lender) or Section 19.5 (Mitigation Obligations; Replacement of Lenders) or comparable provisions to those described in Section 3.2 (Right of Repayment and Cancellation in Relation to a Single Facility Lender) or Section 19.5 (Mitigation Obligations; Replacement of Lenders) under a Facility Agreement;

 

  (iii)

a voluntary prepayment that is financed with proceeds of Replacement Senior Debt; provided that such prepayment will be pro rata across all then-outstanding Loans (other than Working Capital Debt), except as otherwise required by Section 6.3(a)(i)(C) (Replacement Senior Debt); and

 

  (iv)

a payment or prepayment to a Senior Creditor if such payment or prepayment is made in the applicable circumstances set forth in sub-clauses (B), (C), (D) and (E) of Section 2.3(a)(ii) (Payments and Prepayments – Pro Rata Payment of Senior Debt Obligations) of the Common Security and Account Agreement.

 

-14-

Calcasieu Pass - Common Terms Agreement


  3.8

Reductions and Cancellations of Facility Debt Commitments

 

  (a)

The Borrower may cancel Facility Debt Commitments, in whole or in part, in multiples of $5,000,000, pro rata among each Facility Lender (except, in each case, in the case of a cancellation of Facility Debt Commitments in accordance with the Facility Agreement, as specified in Section 6.3(a)(viii) (Replacement Senior Debt) or otherwise in the case where the Borrower is entitled to make a non-pro rata cancellation or prepayment pursuant to Section 3.2 (Right of Repayment and Cancellation in Relation to a Single Facility Lender) and Section 3.7 (Pro Rata Payment)), subject to any minimum cancellation amounts required under the Facility Agreement, by giving at least three (3) Business Days’ prior written notice to the Intercreditor Agent and the applicable Facility Agent or such other notice period required under the applicable Facility Agreement; provided that a notice of cancellation may state that such notice is conditioned upon the effectiveness of other credit facilities or debt instruments in respect of Replacement Senior Debt, in which case such notice may be revoked by the Borrower (by written notice to the Intercreditor Agent and the applicable Facility Agent on or prior to the specified effective date) if such condition is not satisfied.

 

  (b)

Within 30 days of the date of the notice of cancellation delivered in accordance with sub-clause (a) above, the Borrower shall pay any Breakage Costs incurred by any Facility Lender as a result of such notice and revocation.

 

  (c)

The Borrower may not make a voluntary cancellation under this Section 3.8 (Reductions and Cancellations of Facility Debt Commitments) with respect to the Term Loans prior to the Project Completion Date unless it certifies to the Intercreditor Agent (and the Independent Engineer concurs with such certification in writing) that such voluntary cancellation shall not result in the Obligors’ having an insufficient amount of funded or committed capital to fund (on the basis of all other available funds, including funds in the Construction Account, remaining Term Loan Commitments and/or the proceeds of any Replacement Senior Debt to be deposited into the Construction Account concurrently with such cancellation) the remaining expenditures required in order to achieve the Project Completion Date by the Date Certain in accordance with the Construction Budget and Schedule.

 

  (d)

Notwithstanding anything in this Section 3.8 (Reductions and Cancellations of Facility Debt Commitments) to the contrary, the procedure for cancellation related to a mandatory prepayment pursuant to Section 3.4 (Mandatory Prepayments) shall be subject to the terms of the applicable mandatory prepayment in Section 3.4 (Mandatory

 

-15-

Calcasieu Pass - Common Terms Agreement


  Prepayments) or elsewhere in the Finance Documents and not this Section 3.8 (Reductions and Cancellations of Facility Debt Commitments).

 

  3.9

Late Payments

Except as otherwise provided under any Facility Agreement, if any amounts required to be paid by the Borrower under this Agreement or the other Finance Documents (including principal or interest payable on any disbursement and any fees and other amounts otherwise payable to any Secured Party) remain unpaid after such amounts are due (whether at stated maturity, by acceleration or otherwise), the Borrower shall pay interest on the overdue amount (including, to the extent allowable under applicable law, on overdue interest) from the date due until such past due amounts are paid in full at a per annum rate equal to the Default Rate and such interest shall be payable on demand.

 

  3.10

No Borrowing or Reinstatement

No amounts of Loans which have been cancelled, repaid or prepaid in accordance with this Article 3 (Repayment, Prepayment and Cancellation) and the relevant Facility Agreement may be reborrowed; provided that Working Capital Debt may be repaid and reborrowed in accordance with the terms of its applicable Facility Agreement.

 

4.

CONDITIONS PRECEDENT

 

  4.1

Conditions to Closing Date and Initial Advance

The Closing and the obligation of each Facility Lender to make available its Initial Advance shall be subject to the satisfaction or waiver by each of the Facility Lenders of each of the following, and no other, common conditions precedent, in each case in form and substance reasonably satisfactory to, each of the Facility Lenders, and, where applicable, with sufficient copies for, each Facility Agent acting on the instructions of the Facility Lenders under the applicable Facility Agreement:

 

  (a)

Execution and Delivery of the Finance Documents. Receipt by the Facility Lenders, Collateral Agent and the Intercreditor Agent of true, complete and correct copies of the Finance Documents (other than Direct Agreements, which are addressed in clause (b) (Delivery of Material Project Agreements; Direct Agreements) below) and by the Account Bank of the Common Security and Account Agreement, executed and delivered by the parties thereto;

 

  (b)

Delivery of Material Project Agreements; Direct Agreements. Receipt by the Facility Lenders and the Intercreditor Agent of:

 

-16-

Calcasieu Pass - Common Terms Agreement


  (i)

The LNG SPAs, under which LNG Buyers have committed to purchase a quantity of LNG equal to not less than the Base Committed Quantity, each of which shall have been duly authorized, executed and delivered by the parties thereto; and

 

  (A)

as to which (1) all conditions precedent thereunder shall have been satisfied or waived by or concurrently with the CP Satisfaction Date, (2) the CP Satisfaction Date shall occur on or prior to the date of the Initial Advance, (3) no event of LNG SPA Force Majeure shall have occurred and be continuing and (4) no default, event of default or other event or condition shall have occurred and be continuing that provides the applicable LNG Buyer the right to cancel or terminate such LNG SPA in accordance with the terms thereof;

 

  (B)

a certificate of the Obligor that is party to such agreement certifying that (1) the copy of such agreement is a true, correct and complete copy of such document, and (2) such agreement is in full force and effect and no term or condition of such agreement has been amended from the form thereof delivered to the Facility Lenders prior to the Closing Date (other than amendments in accordance with the Finance Documents and provided to the Intercreditor Agent); and

 

  (C)

a Direct Agreement, either substantially in the form attached as Schedule G (Forms of Direct Agreement) of the Common Security and Account Agreement (or otherwise reasonably acceptable to the Facility Lenders); and

 

  (ii)

with respect to each Material Project Agreement (other than any Subsequent Material Project Agreement or any Replacement Material Contract and other than as provided in sub-clause (i) above with respect to the LNG SPAs):

 

  (A)

a copy of such agreement (other than any Restricted Document which shall be delivered in accordance with the requirements of Section 12.6(c) (Confidentiality) of the Common Security and Account Agreement and Section 23.7 (Confidentiality) below), which shall have been duly authorized, executed and delivered by the parties thereto, as to which no force majeure event (as defined in each such Material Project Agreement) has occurred and is continuing;

 

-17-

Calcasieu Pass - Common Terms Agreement


  (B)

a certificate of the Obligor that is party to such agreement certifying that (1) the copy of such agreement is a true, correct and complete copy of such document, and (2) such agreement is in full force and effect and no term or condition of such agreement has been amended from the last form thereof delivered to the Facility Lenders prior to the Closing Date (other than amendments in accordance with the Finance Documents and provided to the Intercreditor Agent);

 

  (C)

a Direct Agreement, either substantially in the form attached as Schedule G (Forms of Direct Agreement) of the Common Security and Account Agreement (or otherwise reasonably acceptable to the Collateral Agent), with each counterparty to such agreement, to the extent such Direct Agreement is required to be delivered by the Closing Date pursuant to Section 3.4 (Direct Agreements) of the Common Security and Account Agreement; and

 

  (iii)

with respect to each Material Project Agreement (other than any Subsequent Material Project Agreement or any Replacement Material Contract):

 

  (A)

a copy of all performance security, letters of credit and guarantees (1) required to be delivered under each Material Project Agreement by the Material Project Counterparties as of the Closing Date and (2) delivered by one or more parent companies of the Pledgor to Material Project Counterparties (all of which, for the avoidance of doubt, will be replaced by Letters of Credit following the Closing).

 

  (iv)

all Material Project Agreements that were provided to the Facility Lenders after the date of the Commitment Letter shall be in form and substance satisfactory to the Facility Lenders.

 

  (c)

Material Project Agreement Default. As of the Closing Date, no material default or event of default of any Obligor, and to the Knowledge of each Obligor, no material default or event of default of any counterparty exists under any Material Project Agreement;

 

  (d)

FERC Order. The FERC Order:

 

  (i)

has been obtained by the Borrower with respect to the LNG Facility and by the Guarantor with respect to the TransCameron Pipeline;

 

-18-

Calcasieu Pass - Common Terms Agreement


  (ii)

is in full force and effect;

 

  (iii)

is final and non-appealable; and

 

  (iv)

is free from conditions and requirements:

 

  (A)

the compliance with which could reasonably be expected to have a Material Adverse Effect; or

 

  (B)

that the applicable Obligor does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development except to the extent that failure to satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect;

 

  (e)

Export Authorizations. Each of the FTA Authorization and the Non-FTA Authorization:

 

  (i)

has been obtained by the Borrower;

 

  (ii)

is in full force and effect;

 

  (iii)

is free from conditions or requirements:

 

  (A)

the compliance with which could reasonably be expected to have a Material Adverse Effect; or

 

  (B)

that the Borrower does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development except to the extent that failure to so satisfy such condition could not reasonably be expected to have a Material Adverse Effect;

 

  (f)

Opinions from Counsel. Receipt by the Intercreditor Agent and the Credit Facility Secured Parties of the legal opinions and reliance letters set forth in Schedule C (Table of Requirements for Legal Opinions – Conditions to Closing) and in accordance with the requirements therein, with such changes thereto as may be in form and substance reasonably satisfactory to the Intercreditor Agent;

 

  (g)

Project Development. Receipt by the Intercreditor Agent of true, complete and correct copies of:

 

  (i)

a certificate of the Obligors attaching the Construction Budget and Schedule with respect to the Development, substantially in the form attached as Schedule D - 1 (Construction Budget and Schedule – Construction Budget) and Schedule D - 2 (Construction Budget and Schedule – Construction Schedule) hereto, and

 

-19-

Calcasieu Pass - Common Terms Agreement


certifying that: (A) such budget and schedule is the best reasonable estimate of the information set forth therein as of the date of such certificate; and (B) such budget and schedule is based on assumptions made in good faith and believed reasonable at the time made in light of the legal and factual circumstances then applicable to the Development and is consistent with the requirements of the Transaction Documents;

 

  (ii)

a certificate of the Obligors attaching the Base Case Forecast, which demonstrates compliance with the Base Case Sizing Criteria, and certifying that: (A) the projections in the Base Case Forecast were made in good faith; and (B) the assumptions on the basis of which such projections were made were believed by the Borrower (when made and delivered) to be reasonable and consistent with the Construction Budget and Schedule and the Transaction Documents;

 

  (iii)

a final report of the Independent Engineer (including certifications and discussions therein relating to the adequacy of the contingency relating to the Project to satisfy potential cost overruns with respect to the Development), together with a reliance letter from the Independent Engineer in form and substance reasonably satisfactory to the Credit Facility Agent;

 

  (iv)

a final report prepared by the Market Consultant, together with a reliance letter from the Market Consultant in form and substance reasonably satisfactory to the Credit Facility Agent;

 

  (v)

final reports prepared by the Environmental Consultant, described on Schedule X (Phase I Environmental Assessments) hereto, together with a reliance letter from the Environmental Consultant, each in form and substance reasonably satisfactory to the Credit Facility Agent; and

 

  (vi)

a certificate of the Independent Engineer concurring with the Borrower’s certification in sub-clause (i) above;

 

  (h)

Financial Statements. Receipt by the Intercreditor Agent of:

 

  (i)

a certified copy of the most recent pro forma balance sheet of each Obligor; and

 

  (ii)

to the extent delivered to the Borrower or the Guarantor under any Material Project Agreement, financial statements of the Material Project Counterparties;

 

-20-

Calcasieu Pass - Common Terms Agreement


  (i)

Insurance. Receipt by the Intercreditor Agent of:

 

  (i)

a report from the Insurance Advisor, prepared in accordance with generally accepted consulting practices together with a certificate of the Insurance Advisor confirming that the insurance policies to be provided in compliance with Section 12.28 (Insurance Covenant) conform to the requirements specified in the Finance Documents and are in accordance with Prudent Industry Practices; and

 

  (ii)

a reliance letter from the Insurance Advisor in form and substance reasonably satisfactory to the Credit Facility Agent;

 

  (j)

Real Property.

 

  (i)

Receipt by the Collateral Agent of (A) a Survey and (B) a Title Policy conforming to the requirements specified in the definition of each such term; and

 

  (ii)

Receipt by the Collateral Agent of: (A) an estoppel certificate for the Lease described in clause (a) of the definition of “Leases” that includes a consent in respect of the Access License Agreements described in clauses (a), (d), (e), (f) and (g) of the definition of “Access License Agreements”, (B) an estoppel certificate for the Lease described in clause (b) of the definition of “Leases”, (C) an estoppel certificate from CP Marine Offloading, LLC in respect of the Access License Agreements and (D) an estoppel certificate from the underlying lessors consenting to the Access License Agreement described in clause (b) of the definition of “Access License Agreements”.

 

  (k)

Bank Regulatory Requirements. Receipt by the Intercreditor Agent and each other Finance Party that is a party to this Agreement:

 

  (i)

at least three (3) Business Days prior to the Closing Date, with respect to each of the Collateral Parties, of a certified electronic copy of each of the documents listed in Schedule E (Know Your Customer Documentation) that are required in order for each Facility Lender to carry out all necessary “know your customer” or similar requirements and such other information as may be reasonably required by such Facility Lender to address such requirement, including those reasonably required to ensure compliance with anti-money laundering procedures (including the USA Patriot Act) in its relevant jurisdiction, in each case to the extent not otherwise delivered to the relevant Finance Party at or prior to the Closing Date (and provided that any subsequent changes in such documents or updates to information contained therein shall be so delivered in accordance with this clause (k)(i)); and

 

-21-

Calcasieu Pass - Common Terms Agreement


  (ii)

at least three (3) Business Days prior to the Closing Date, a Beneficial Ownership Certification from the Borrower if it qualifies as a “legal entity customer” under the Beneficial Ownership Regulation;

 

  (l)

Officer’s Certificates. Receipt by the Intercreditor Agent of a copy of a duly executed certificate of each of the Collateral Parties and, with respect to sub-clauses (i)—(iii) below, of each Affiliated Service Counterparty:

 

  (i)

attaching a copy of the Constitutional Documents of each of the Collateral Parties and each Affiliated Service Counterparty, together with any amendments thereto (and certifying that such Constitutional Documents have not been revoked or amended since the date of the attached Constitutional Documents);

 

  (ii)

attaching copies of resolutions approving the Collateral Parties’ and the Affiliated Service Counterparties’ entry into the Finance Documents and Material Project Agreements, as applicable (and certifying that such resolutions have not been revoked or amended since the date of adoption thereof);

 

  (iii)

attaching incumbency certificates in respect of signatories; and

 

  (iv)

certifying that the conditions in clauses (c) (Material Project Agreement Default) and (m) (Representations and Warranties) of this Section 4.1 (Conditions to Closing Date and Initial Advance) have been met;

 

  (m)

Representations and Warranties. (i) Each of the representations and warranties of the Obligors as set forth under Article 5 (Representations and Warranties of the Obligors) of this Agreement is true and correct in all material respects (except for those qualified by materiality, each of which shall be true and correct in all respects) as to such Obligor on and as of the Closing Date as if made on and as of the Closing Date (or if stated to have been made solely as of an earlier date, as of such earlier date);

 

  (n)

Establishment of Accounts. Receipt by the Collateral Agent (with a copy to the Intercreditor Agent) of evidence that each of the Accounts required to be in existence as of the Closing Date has been established as required pursuant to the Common Security and Account Agreement;

 

  (o)

Lien Search: Perfection of Security. Receipt by the Collateral Agent of copies or evidence, as the case may be, of the following actions in connection with the perfection of the Collateral:

 

  (i)

completed requests for information or copies of the UCC search reports and tax lien, judgment and litigation search reports for the

 

-22-

Calcasieu Pass - Common Terms Agreement


State of Delaware and the State of Louisiana, and any other jurisdiction reasonably requested by any of the Facility Agents that name each Obligor or the Pledgor as debtor, together with copies of each UCC financing statement, fixture filing or other filings listed therein, which evidences no Liens on the Collateral, other than Permitted Liens; all dated within 15 Business Days prior to the Closing Date;

 

  (ii)

UCC financing statements, fixture filings or other filings reflecting the Liens granted pursuant to the Common Security and Account Agreement and the other Security Documents that any of the Facility Agents may deem necessary or desirable in order to perfect the first priority Liens (subject to Permitted Liens) created thereunder; and

 

  (iii)

the Collateral is subject to the perfected first priority Lien (subject only to Permitted Liens) established pursuant to the Security Documents;

 

  (p)

Fees; Expenses. Irrevocable instructions for the payment to each of the Facility Agents for its own account, or for the account of the relevant Facility Lender entitled thereto, of all fees due and payable as of the Closing Date pursuant to the Finance Documents, and all costs and expenses (including reasonable costs, fees and expenses of legal counsel and Consultants) payable thereunder for which reasonably detailed invoices have been presented to the Borrower at least three (3) Business Days prior to the Closing Date;

 

  (q)

Authority to Conduct Business. Receipt by the Intercreditor Agent of satisfactory evidence, including certificates of good standing, dated no more than five (5) Business Days prior to the Closing Date, from the Secretary of the State of Louisiana and the Secretary of State of the State of Delaware, as applicable, of the authority of each Collateral Party and Affiliated Service Counterparty to carry on its business;

 

  (r)

Total Capitalization. The aggregate Term Loan Commitments are not more than 75% of the then-current estimate of Project Costs projected in the Construction Budget and Schedule as of the Closing Date to be incurred by the Obligors for the Development;

 

  (s)

Lien Waivers. Receipt by the Intercreditor Agent of Lien Waivers as have then been required pursuant to each of the Material Construction Contracts;

 

  (t)

Flood Insurance. Receipt by each of the Facility Lenders of the following flood coverage documents from the Borrower, in each case to be satisfactory to each of the Facility Lenders:

 

-23-

Calcasieu Pass - Common Terms Agreement


  (i)

a completed “Standard Flood Hazard Determination Form” of the Federal Emergency Management Agency and any successor Governmental Authority performing a similar function (a “Flood Certificate”) with respect to the anticipated real property comprising the LNG Facility Site (including leasehold interests therein) expected to be included in the Collateral (“Mortgaged Property”), which Flood Certificate shall:

 

  (A)

be addressed to the Credit Facility Agent;

 

  (B)

provide for “life of loan” monitoring; and

 

  (C)

otherwise comply with the National Flood Insurance Program created by the US Congress pursuant to the National Flood Insurance Act of 1968, the Flood Disaster Protection Act of 1973, the National Flood Insurance Reform Act of 1994 and the Flood Insurance Reform Act of 2004 and any successor statutes (the “Flood Program”);

 

  (ii)

if the Flood Certificate states that any structure comprising a portion of the anticipated Mortgaged Property will be located in a Special Flood Hazard Area, the Borrower’s written acknowledgment of receipt of written notification from the Credit Facility Agent and any Facility Lender requesting the same:

 

  (A)

as to the existence of such Mortgaged Property; and

 

  (B)

as to whether the community in which such Mortgaged Property will be located is participating in the Flood Program;

 

  (u)

Notes. Receipt of copies of the notes requested by the Facility Lenders pursuant to their Facility Agreement, as applicable, duly authorized, executed and delivered by the Borrower;

 

  (v)

Litigation; Regulatory Action. There are no actions, suits, proceedings, investigations or similar actions pending or, to the knowledge of each Obligor, threatened (in writing) against such Obligor that have had or could reasonably be expected to have a Material Adverse Effect;

 

  (w)

Releases under Sponsor Loan. Receipt by the Intercreditor Agent of a release letter, in form and substance reasonably satisfactory to the Intercreditor Agent, confirming that all security interests, pledges, encumbrances, and/or other Liens on the Sponsor’s Equity Interests in the Obligors securing the Sponsor Loan have been released or shall be released, or assigned to the Collateral Agent in the case of the Mortgage, concurrently with the consummation of the transactions contemplated by the Transaction Documents;

 

-24-

Calcasieu Pass - Common Terms Agreement


  (x)

No Force Majeure. To the knowledge of the Obligors, no event of force majeure (as defined under the applicable Material Project Agreement) has occurred and is continuing under any Material Project Agreement the consequences of which could reasonably be expected to have a Material Adverse Effect;

 

  (y)

Absence of Default. No Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing on such date or could reasonably be expected to result from the consummation of the transactions contemplated by the Transaction Documents;

 

  (z)

Equity Funding. At least $1,825,800,000 shall have been contributed to the Borrower either (i) prior to the Closing Date (and verified in writing by the Independent Engineer) or (ii) on the Closing Date and deposited into the Construction Account (as verified by the Account Bank) concurrently with the consummation of the transactions contemplated by the Transaction Documents (any such Equity Funding contemplated by this clause (z)(ii), the “Closing Date Equity Funding”);

 

  (aa)

Notice to Proceed. Issuance by the Borrower and the Guarantor, as applicable, of the “Notice to Proceed” or “FNTP”, as applicable, under and in accordance with each of the Material Construction Contracts;

 

  (bb)

Delivery of Material Permits. The Intercreditor Agent has received a copy of each material Permit (including the FERC Order, the FTA Authorization and Non-FTA Authorization);

 

  (cc)

Funds Flow Memorandum. Delivery by the Borrower of the memorandum setting forth the flow of funds on the Closing Date; and

 

  (dd)

Due Diligence CPs. The Borrower shall have satisfied each of the following conditions:

 

  (i)

the Borrower shall have received written confirmation from BHGE that the basis of design of the UOP-delivered pre-treatment systems does not affect any performance guarantee (including any minimum performance guarantee or unconditional performance obligation) under the PIS Purchase Order or LTS Purchase Order;

 

  (ii)

prior to June 30, 2019, extensions of (or confirmations of extensions of) the Material Project Agreements’ longstop dates of June 30, 2019 or earlier such that no Material Project Counterparty will have a termination right if any relevant conditions precedent thereunder were not satisfied as of such longstop dates;

 

-25-

Calcasieu Pass - Common Terms Agreement


  (iii)

execution of an amendment to the EPC Contract addressing certain clarifications;

 

  (iv)

execution of a Change Order to the EPC Contract resolving the “Open Cost Items” for purposes of the EPC Contract;

 

  (v)

delivery or written confirmation of the agreed list of guaranteed milestone dates under the LTS Purchase Order; and

 

  (vi)

execution of a Change Order under the PIS Purchase Order that confirms the agreed delivery points under the PIS Purchase Order.

 

  4.2

Conditions to Each Advance

Except as specified in Section 14.2(b) (Project Completion Date Waterfall – Final Advance of Term Loans), the obligation of each Facility Lender (other than the Working Capital Lenders) to make available any Advance of Initial Senior Debt is subject to the satisfaction or waiver of the following (and, in the case of any Advance other than the Initial Advance, no other) common conditions precedent:

 

  (a)

Disbursement Request. Receipt by the applicable Facility Agent of a Disbursement Request substantially in the form set forth in Schedule B-1 (Disbursement Request Form (Term Loans)) (and in such form as required pursuant to each Facility Agreement), which shall:

 

  (i)

be for an amount that does not exceed (A) Project Costs reasonably expected to be due or incurred within the next 45 days succeeding the date of the proposed Advance minus (B) the amount estimated to be on deposit in the Construction Account on the date of such Advance;

 

  (ii)

include a certification from the Borrower (and, in the case of the certifications set forth in sub-clauses (A), (B), (C) and (D) below, to which the Independent Engineer reasonably concurs):

 

  (A)

that the Independent Engineer has received from the Borrower (1) a detailed breakdown of the Project Costs to be funded pursuant to such Advance and (2) copies of or access to each invoice related to Project Costs incurred since the most recent Advance (or in the case of the first Advance after the Closing Date, since Closing) that is for more than $250,000 (excluding any invoices related to Permitted Hedging Instruments, Senior Debt or any Permitted Finance Costs and non-construction transaction costs and expenses) and, to the extent necessary, additional invoices so that the Independent Engineer has received invoices with respect to each prior Advance representing at

 

-26-

Calcasieu Pass - Common Terms Agreement


  least 90% of the applicable Project Costs (excluding any invoices related to Permitted Hedging Instruments, Senior Debt or any Permitted Finance Costs and non-construction transaction costs and expenses) incurred since the most recent Advance;

 

  (B)

that the amount of the Advance being requested (1) is supported by such information provided by the Obligors to the Independent Engineer and certified by the Borrower as true, correct and complete with respect to the matter under review or (2) with respect to any evidence that constitutes estimated information, is based on reasonable good faith projections reasonably satisfactory to the Independent Engineer; provided that the Independent Engineer will not be required to evaluate the reasonableness of the projections with respect to funds used or funds related to payments under Permitted Hedging Instruments, Senior Debt, any Permitted Finance Costs and non-construction transaction costs or expenses;

 

  (C)

(1) that the construction of the Project Facilities is proceeding substantially in accordance with the construction schedule set out in the Construction Budget and Schedule or, if not so proceeding, any delays shall not be reasonably expected to cause the Project Completion Date to otherwise not be achieved by the Date Certain, (2) as to the current utilization of previous Advances and (3) that the Facility Debt Commitments and funds on deposit in the Construction Account, Contingency Reserve Account and the Permitted Finance Costs Reserve Account (including any Equity Funding remaining on deposit in the Construction Account) are sufficient to achieve the Project Completion Date by the Date Certain;

 

  (D)

that the Independent Engineer has received evidence that the full amount of the proceeds of the last preceding Advance has been either (1) paid in accordance with the Finance Documents or (2) retained in the Construction Account;

 

  (E)

that construction reports that are then due pursuant to Section 10.4 (Construction Reports) have been provided to the Intercreditor Agent;

 

  (F)

that the Borrower reasonably believes that the Project Completion Date shall occur on or prior to the Date Certain;

 

-27-

Calcasieu Pass - Common Terms Agreement


  (G)

that each of the conditions in clauses (b) (Representations and Warranties), (c) (Absence of Default), (d) (Permits), (e) (Collateral), (i) (Senior Debt/Equity Ratio) and (j) (Export Authorizations) below have been met; and

 

  (H)

none of the Construction Contractors has sought a Change Order to which such Construction Contractor is entitled for any EPC Change in Law as contemplated under Section 12.1 (Changes in the Work) of the EPC Contract or the corresponding provision of the Material Construction Contract that would, taking into account the increase in the contract price thereunder, cause the condition set forth in sub-clause (C) above not to be satisfied; and

 

  (iii)

include either (A) a list of all Change Orders for more than $10 million not theretofore submitted to the Intercreditor Agent, together with a statement by the Borrower that copies of the same have been submitted to the Independent Engineer prior to the date of the applicable Disbursement Request or (B) a Borrower statement that all Change Orders for more than $10 million have previously been submitted to the Intercreditor Agent;

 

  (b)

Representations and Warranties. Each of the Repeated Representations made by such Obligor is true and correct in all material respects, except for those representations and warranties that are qualified by materiality, which shall be true and correct in all respects, as to such Obligor on and as of the date of such Advance as if made on and as of such date (or, if stated to have been made solely as of an earlier date, as of such earlier date);

 

  (c)

Absence of Default. No Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing on such date or could reasonably be expected to result from the consummation of the transactions contemplated by the Transaction Documents;

 

  (d)

Permits. The Intercreditor Agent shall have received a copy of each material Permit to the extent required by Section 10.4(b)(x) (Construction Reports).

 

  (e)

Collateral. The Collateral is subject to the perfected first priority Lien (subject only to Permitted Liens) in accordance with the requirements of, and established pursuant to, the Security Documents.

 

  (f)

Real Property. Receipt by the Collateral Agent of a Disbursement Endorsement;

 

-28-

Calcasieu Pass - Common Terms Agreement


  (g)

Lien Waivers. Receipt by the Intercreditor Agent of Lien Waivers as have then been required pursuant to each of the Material Construction Contracts;

 

  (h)

Fees; Expenses. Receipt by each of the Facility Agents for its own account, or for the account of the relevant Facility Lender entitled thereto, of, or issuance of irrevocable instructions to pay from the proceeds of the Advance, all fees due and payable on and as of the date of the Advance pursuant to the Finance Documents, and all costs and expenses (including reasonable costs, fees and expenses of legal counsel and Consultants) payable thereunder for which reasonably detailed invoices have been presented to the Borrower at least three (3) Business Days prior to the Advance;

 

  (i)

Senior Debt/Equity Ratio. The Senior Debt/Equity Ratio shall be no greater than 75:25, as confirmed by the Borrower; and

 

  (j)

Export Authorizations. No Impairment of any Required Export Authorization with respect to any Required LNG SPA has occurred and is continuing that could reasonably be expected to result in a Material Adverse Effect. For the avoidance of doubt, if such an Impairment ceases to be continuing, whether as a result of an Export Authorization Remediation or otherwise, this condition will be deemed fulfilled.

 

  4.3

Conditions to Each Advance under the Working Capital Facility

The obligation of each Working Capital Lender to make available any Advance of Initial Senior Debt is subject to the satisfaction or waiver of the following (and no other) common conditions precedent:

 

  (a)

Disbursement Request. If such disbursement request is a request for Working Capital Loans, receipt by the Credit Facility Agent of a Disbursement Request substantially in the form set forth in Schedule B-2 (Disbursement Request Form (Working Capital Loans));

 

  (b)

Issuance Request. If such disbursement request is a request for Letters of Credit, receipt by the Credit Facility Agent of an Issuance Request substantially in the form set forth in Schedule B-3 (Issuance Request Form (Letters of Credit));

 

  (c)

Absence of Default. No Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing on such date or could reasonably be expected to result from the consummation of the transactions contemplated by the Transaction Documents; and

 

  (d)

Representations and Warranties. Each of the Repeated Representations made by each Obligor is true and correct in all material respects, except

 

-29-

Calcasieu Pass - Common Terms Agreement


for those representations and warranties that are qualified by materiality, which shall be true and correct in all respects, as to such Obligor on and as of the date of such Advance as if made on and as of such date (or, if stated to have been made solely as of an earlier date, as of such earlier date).

 

  4.4

Satisfaction of Conditions

 

  (a)

In relation to the Closing and the Initial Advance:

 

  (i)

if each of the conditions precedent set forth in Section 4.1 (Conditions to Closing Date and Initial Advance) and Section 4.2 (Conditions to Each Advance) has been satisfied or waived, (x) the Borrower shall deliver to the Intercreditor Agent a certificate to such effect (such certificate, the “Closing Conditions Certificate”) and (y) the Intercreditor Agent shall deliver the Closing Conditions Certificate to the Credit Facility Agent and unless a separate instrument effecting any such waiver has been signed by each of the relevant Parties, the Intercreditor Agent shall countersign the Closing Conditions Certificate and deliver the same to the Credit Facility Agent, solely for the purpose of acknowledging receipt of the Closing Conditions Certificate and confirming such waivers (if any), and deliver such countersigned certificate to the Borrower or otherwise provide the Borrower with a written confirmation of its receipt of the Borrower’s Closing Conditions Certificate (such countersigned Closing Conditions Certificate, or such Closing Conditions Certificate together with the Intercreditor Agent’s written confirmation of receipt thereof, is collectively referred to as the “Closing Notice”). The occurrence of the Closing and the obligation of each Term Lender to make the Initial Advance is subject to the Intercreditor Agent’s delivery of the Closing Notice to the Borrower prior to or concurrently with the Closing; and

 

  (ii)

the Disbursement Request with respect to the Initial Advance may be delivered by the Borrower at any time on or following (and in no event prior to) the delivery of the Closing Notice, which notice must be delivered no later than 3:00 p.m., New York City time, on the Business Day prior to the proposed Advance and otherwise in accordance with the applicable requirements set forth in the Credit Facility Agreement.

 

  (b)

In relation to each Advance of Loans made under any Additional Senior Debt such Advance shall be subject to satisfaction or waiver of such conditions precedent as may be set forth in the Facility Agreement for such Additional Senior Debt.

 

  (c)

In relation to each Advance of Loans under a Facility Agreement, the Intercreditor Agent may waive one or more conditions precedent set out in

 

-30-

Calcasieu Pass - Common Terms Agreement


this Article 4 (Conditions Precedent) or any additional conditions to disbursements under the applicable Facility Agreement upon receiving instructions regarding any such waiver from the Facility Agent under the Facility Agreement related to such Advance of Loans and the Intercreditor Agent shall promptly notify the Borrower of such waiver.

 

  (d)

The conditions precedent in this Article 4 (Conditions Precedent) and under any Facility Agreement shall be interpreted to permit a single certificate from a Party certifying as to matters required by multiple sections and subsections of this Article 4 (Conditions Precedent).

 

5.

REPRESENTATIONS AND WARRANTIES OF THE OBLIGORS

 

  5.1

Initial Representations and Warranties of the Obligors

Each Obligor makes the following, and no other, common representations and warranties to each Facility Lender. Each such representation and warranty is made at the Closing Date only:

 

  (a)

Conduct of Business

In respect of each Obligor, it is not engaged in any business other than the Development as contemplated by its Constitutional Documents and the Transaction Documents then in effect.

 

  (b)

Material Permits

 

  (i)

All material Permits (other than the FERC Order and the Export Authorizations) necessary for the Development are set forth in Schedule F (Material Permits) hereto, and:

 

  (A)

as to those identified as such in the relevant schedule, have been duly obtained, were validly issued, are in full force and effect, and are not the subject of any pending appeal (or if subject to any appeal, such appeal does not have a reasonable probability of success and the applicable permit remains effective during such appeal) and all applicable fixed time periods for appeal set forth in the Government Rules pursuant to which such Permits were issued have expired or are Permits that do not have limits on appeal periods; or

 

  (B)

as to those identified as such in the relevant schedule, are expected by the Obligors to be obtained in the ordinary course by the time they are necessary for the Development; and

 

-31-

Calcasieu Pass - Common Terms Agreement


  (C)

in the case of the Permits described in sub-clause (A) above, are, or, in the case of the Permits described in sub-clause (B) above, are reasonably expected to be, free from conditions or requirements:

 

  (1)

the compliance with which could reasonably be expected to have a Material Adverse Effect; or

 

  (2)

which the Obligors do not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development for which such Permit is necessary, except to the extent that a failure to so satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect.

 

  (ii)

In respect of each Obligor, to its Knowledge, there is no action, suit or proceeding pending with respect to any material Permit set forth in Schedule F (Material Permits) attached hereto (not including the FERC Order or any Export Authorization) that could reasonably be expected to result in a Material Adverse Effect or if subject to any appeal, such appeal does not have a reasonable probability of success and the applicable permit remains effective during such appeal.

 

  (c)

Compliance with Laws

Except to the extent already contemplated under this Article 5 (Representations and Warranties of the Obligors) hereof, each Obligor is in material compliance with all material applicable Government Rules.

 

  (d)

No Employees

None of the Obligors has any current or former employees.

 

  (e)

Labor Matters

In respect of each Obligor, no strikes, lockouts or slowdowns in connection with it or the Project Facilities exist or, to its Knowledge, are threatened that could reasonably be expected to have a Material Adverse Effect.

 

-32-

Calcasieu Pass - Common Terms Agreement


  (f)

Legal Name and Place of Business

 

  (i)

The full and correct legal name, type of organization and jurisdiction of organization of each of the Obligors is as follows:

 

  (A)

Venture Global Calcasieu Pass, LLC, a limited liability company organized under the laws of the State of Delaware; and

 

  (B)

TransCameron Pipeline, LLC, a limited liability company organized under the laws of the State of Delaware.

 

  (ii)

Except as set forth on Schedule 5.1(f)(ii) (Prior Locations), no Obligor has ever changed its name or location (as defined in Section 9-307 of the UCC); and

 

  (iii)

On the Closing Date, the chief executive offices of the Obligors are located at 1001 19th Street North, Suite 1500, Arlington, VA 22209.

 

  (g)

Reserved

 

  (h)

Sanctions, Anti-Corruption Laws and USA Patriot Act

The use of the proceeds of the Loans does not violate, and will not cause a violation by any person of, any Applicable Anti-Corruption Laws, Anti-Terrorism and Money Laundering Laws, or Sanctions, and none of the Obligors, the Sponsor or any of their respective Affiliates, nor, to the Knowledge of the Obligors, any of their respective directors, officers or employees, is:

 

  (i)

the target of Sanctions administered by the United States, including by OFAC and by the US Department of State, the European Union, any EU member state, or Her Majesty’s Treasury of the United Kingdom;

 

  (ii)

a Person listed in any Sanctions-related list of sanctioned Persons maintained by the United States, including by OFAC and the U.S. Department of State, by the United Nations Security Council, the European Union, any EU member state, or the Her Majesty’s Treasury of the United Kingdom;

 

  (iii)

a Person located, organized or resident in a country, territory, or region that is, or whose government is, the target of Sanctions under OFAC or by the US Department of State, the European Union, any EU member state, or Her Majesty’s Treasury or the United Kingdom, , including, without limitation, currently the Crimea region, Cuba, Iran, North Korea, and Syria;

 

-33-

Calcasieu Pass - Common Terms Agreement


  (iv)

a Person owned or controlled a Person, country, territory, or region in (i) through (iii) (each such person in (i) through (iv), a “Sanctioned Person”); or

 

  (v)

the subject of any action or investigation by any Governmental Authority with respect to any actual or alleged violation of any Applicable Anti-Corruption Laws, Anti-Terrorism and Money Laundering Laws, or Sanctions.

The Obligors and the Sponsor, and, to the Knowledge of the Obligors, their respective Affiliates, directors, officers and employees, are in material compliance with Applicable Anti-Corruption Laws, Anti-Terrorism and Money Laundering Laws, and Sanctions.

The Obligors and the Sponsor and, to the Knowledge of the Obligors, their respective Affiliates have instituted and maintain policies and procedures reasonably designed to promote compliance with Applicable Anti-Corruption Laws, Anti-Terrorism and Money Laundering Laws, and Sanctions.

 

  (i)

Financial Condition

In respect of each Obligor, there has been no change in its financial condition, operations or business since the date of the financial statements referred to in Section 4.1(h) (Conditions to Closing Date and Initial Advance – Financial Statements) that could reasonably be expected to have a Material Adverse Effect.

 

  (j)

Information; Projections

In respect of each Obligor, except as otherwise disclosed by it in writing, no information furnished in writing to the Senior Creditors by or on behalf of it in connection with the transactions contemplated by the Transaction Documents or delivered to the Collateral Agent, any Consultant or a Facility Agent in connection therewith (or their counsel), when taken as a whole, contains, as of the date of such information, any untrue statement of a material fact pertaining to it or the Development or omits to state a material fact pertaining to it or the Development necessary to make the statements contained herein or therein not misleading in any material respect (provided that no representation or warranty is made with respect to any forecast, estimate, forward-looking information, information of a general economic or general industry nature or pro forma calculation made in the Construction Budget and Schedule, this Agreement or Base Case Forecast, including with respect to the start of operations of the Project

 

-34-

Calcasieu Pass - Common Terms Agreement


Facilities, the Project Completion Date, the Closing Date, final capital costs or operating costs of the Development, oil prices, Gas prices, LNG prices, electricity prices, Gas reserves, rates of production, Gas market supplies, LNG market demand, exchange rates or interest rates, rates of taxation, rates of inflation, transportation volumes or any other forecasts, projections, assumptions, estimates or pro forma calculations, except that they are based on assumptions made in good faith and believed reasonable at the time made in light of the legal and factual circumstances then applicable to the Development, and it makes no representation as to the actual attainability of any projections set forth in the Base Case Forecast or Construction Budget and Schedule, or any such other items listed in this proviso). Without limiting the generality of the foregoing, no representation or warranty shall be made by any Obligor as to any information or material provided by a Consultant (except to the extent such information or material originated with such Obligor).

 

  (k)

Environmental and Social

Except as set forth in Schedule G (Disclosure Schedule) hereto:

 

  (i)

Except as could not reasonably be expected to result in a Material Adverse Effect, each Obligor and the Project Facilities are, and have been, in compliance with all applicable Environmental Laws;

 

  (ii)

there are no past or present facts, circumstances, conditions, events or occurrences, including Releases of Hazardous Materials by the Obligors or with respect to the Project Facilities or any Real Estate on which any Project Facilities are located, that could reasonably be expected to give rise to any Environmental Claims that could reasonably be expected to have a Material Adverse Effect or cause the Project Facilities to be subject to any restrictions on ownership, occupancy, use or transferability under any Environmental Laws that could reasonably be expected to have a Material Adverse Effect (excluding restrictions on the transferability of Permits upon the transfer of ownership of assets subject to such Permit);

 

  (iii)

Hazardous Materials have not at any time been Released at, on, under or from the Project Facilities, or any Real Estate on which they are situated, by an Obligor or, to the Knowledge of such Obligor, other Persons, other than in material compliance at all times with all applicable Environmental Laws or in such manner as otherwise could not reasonably be expected to result in a Material Adverse Effect;

 

  (iv)

there have been no material environmental investigations, studies, audits, reviews or other analyses relating to environmental site conditions that individually or in the aggregate could reasonably be

 

-35-

Calcasieu Pass - Common Terms Agreement


  expected to have a Material Adverse Effect and that have been conducted by, or that are in the possession or control of, the Obligors in relation to the Project Facilities, or any Real Estate on which they are situated, that have not been provided to the Collateral Agent; and

 

  (v)

the Obligors have not received any letter or request for information under Section 104 of CERCLA, or comparable state laws, and to the Knowledge of the Obligors, none of the operations of the Obligors is the subject of any investigation by a Governmental Authority evaluating whether any remedial action is needed to respond to a Release or threatened Release of any Hazardous Materials relating to the Project Facilities, or any Real Estate on which they are situated, or at any other location, including any location to which the Obligors have transported, or arranged for the transportation of, any Hazardous Materials with respect to the Development, which, in each case above, could reasonably be expected to have a Material Adverse Effect.

 

  (l)

Reserved

 

  (m)

Taxes

In respect of each Obligor, it (or, for the purposes of this clause (m) as it relates to US federal income taxes, if it is a disregarded entity for US federal income tax purposes, its owner for US federal income tax purposes) has timely filed or caused to be filed all income tax returns that are required to be filed and all other material tax returns that are required to be filed, and has paid (i) all Taxes shown to be due and payable on such returns or on any material assessments made against it or any of its property and (ii) all other material Taxes imposed on it or its property by any Governmental Authority (other than Taxes that are being contested in good faith by appropriate proceedings diligently conducted and for which adequate reserves are being maintained in accordance with GAAP), and no tax Liens (other than Permitted Liens) have been filed and no claims are being asserted with respect to any such Taxes (other than claims which are being contested in good faith).

 

  (n)

Reserved

 

  (o)

Regulatory Matters

 

  (i)

None of the Obligors is subject to regulation:

 

  (A)

under Section 3 of the Natural Gas Act;

 

-36-

Calcasieu Pass - Common Terms Agreement


  (B)

as a “natural-gas company” as such term is defined in the Natural Gas Act;

 

  (C)

under PUHCA; or

 

  (D)

under the Louisiana Government Rules as a “public utility” or a “gas utility”;

provided that the Borrower is subject to the provisions of Section 3 of the Natural Gas Act (1) for the siting, construction, expansion, and operation of the LNG Facility and (2) with respect to the export of LNG from the LNG Facility; and provided, further, that the Guarantor is subject to Section 7 of the Natural Gas Act with respect to the construction and operation of the TransCameron Pipeline, and each of the Obligors will become subject to provisions of the Natural Gas Act as a “natural-gas company” at such time as the Obligors, as applicable, engage in the transportation of “natural gas” (as such term is defined in the Natural Gas Act) in interstate commerce or the sale in interstate commerce of natural gas for resale; however, the Borrower will be subject to regulation as a “natural-gas company” under the Natural Gas Act only to the extent of natural gas sales pursuant to Part 284, Subpart L of FERC’s regulations.

 

  (ii)

None of the Collateral Agent nor the Senior Creditors, solely by virtue of the execution and delivery of the Finance Documents, the consummation of the transactions contemplated thereby, or the performance of obligations thereunder, shall be or become subject to the provisions of:

 

  (A)

Section 3 of the Natural Gas Act;

 

  (B)

the Natural Gas Act as a “natural-gas company” as such term is defined in such Act;

 

  (C)

PUHCA; or

 

  (D)

the Louisiana Government Rules as a “public utility” or a “gas utility”.

 

  (p)

Transactions with Affiliates

In respect of each Obligor, it has not entered into any material agreement (other than the Material Project Agreements and any other agreements permitted by Section 12.21 (Transactions with Affiliates)) with the Sponsor or any of its Affiliates on terms and conditions which, in the aggregate, are less favorable to it than those that would be applicable in a

 

-37-

Calcasieu Pass - Common Terms Agreement


comparable agreement with independent parties acting at arm’s length (or, if there is no comparable arm’s-length transaction, then on terms reasonably determined by such Obligor (acting through its board of managers, if applicable) to be fair and reasonable).

 

  (q)

Solvency

In respect of each Obligor, it is and, upon the incurrence of any Senior Debt Obligations, and after giving effect to the transactions and the incurrence of Indebtedness in connection therewith, shall be Solvent.

 

  (r)

Ranking of Senior Debt Obligations

Subject to Section 3.7 (Pro Rata Payment), the Senior Debt Obligations of the Borrower in respect of each Secured Party that is party to the Common Terms Agreement shall rank:

 

  (i)

pari passu in right of payment and otherwise with its Senior Debt Obligations to each other Secured Party under the Finance Documents; and

 

  (ii)

pari passu or senior in right of payment to all other Indebtedness of the Borrower whether now existing or hereafter outstanding.

 

  (s)

Operating Responsibilities

The administrative and operational responsibilities delegated to the Manager and the applicable Operator pursuant to the Administrative Services Agreements and the O&M Agreements, collectively, constitute all the administrative and operational responsibilities necessary to comply with the obligations of the Obligors pursuant to the Transaction Documents.

 

  (t)

Reserved

 

  (u)

Material Project Agreements

 

  (i)

A list of each Material Project Agreement existing on the Closing Date, is attached as Schedule H (Material Project Agreements and Certain Other Contracts) hereto. The Schedule contains details of all amendments, amendments and restatements, supplements, waivers and interpretations modifying or clarifying any of the above. True, correct and complete copies of each of the aforementioned contracts have been delivered to the Intercreditor Agent and certified by the Borrower;

 

-38-

Calcasieu Pass - Common Terms Agreement


  (ii)

To the Knowledge of each Obligor, all Material Project Agreements are in full force and effect;

 

  (iii)

As of the Closing Date, no material default or event of default of any Obligor and, to the Knowledge of each Obligor, no material default or event of default of any counterparty exists under any Material Project Agreement;

 

  (iv)

To the Knowledge of each Obligor, as of the Closing Date, the representations and warranties of the Material Project Counterparties under the Material Project Agreements are true and accurate in all material respects;

 

  (v)

As of the Closing Date, no (A) event of force majeure (as defined under the applicable Material Project Agreement) in respect of which a Material Project Counterparty has sought or would reasonably be expected to seek relief from performance under a Material Project Agreement has occurred and is continuing under any Material Project Agreement or (B) other circumstance exists that would entitle a Material Project Counterparty to terminate a Material Project Agreement or suspend its performance thereunder has occurred and is continuing; and

 

  (vi)

None of the Material Project Agreements has been terminated or otherwise amended, modified, supplemented, transferred, impaired or, to the applicable Obligor’s Knowledge, assigned, in each case except as permitted under Section 8.3 (Amendment of LNG SPAs), Section 12.5(c) (Material Project Agreements), Section 12.5(d) (Material Project Agreements) or Section 12.29(c) (Certain Real Property Rights; Real Property Documents; Leases).

 

  (v)

Equator Principles

As of the Closing Date, the Obligors are in compliance in all material respects with the Equator Principles.

 

  (w)

Litigation

Except as set forth on Schedule G (Disclosure Schedule) hereto, there are no actions, suits, proceedings, investigations or similar actions pending or, to the knowledge of the Obligors, threatened in writing against the Borrower or the Guarantor that would reasonably be expected to result in a Material Adverse Effect.

 

-39-

Calcasieu Pass - Common Terms Agreement


  (x)

Flood Insurance

The Borrower has complied with the covenant in Section 12.28(c) (Insurance Covenant) and otherwise obtained flood insurance for each Flood Hazard Property and such insurance is in full force and effect.

 

  (y)

Liabilities

Except as set forth in Schedule G (Disclosure Schedule) hereto, other than liabilities incurred in connection with the consummation of the transactions contemplated by the Transaction Documents, there are no material liabilities of any Obligor of any kind whatsoever, whether accrued, contingent, absolute, determined, determinable or otherwise that would be required to be reflected on a balance sheet of such Obligor prepared in accordance with GAAP other than those liabilities arising in the ordinary course of business and permitted under the Finance Documents.

 

  (z)

Reserved

 

  (aa)

Reserved

 

  (bb)

Beneficial Ownership Certification

The information included in the Beneficial Ownership Certification is true and correct in all respects.

 

  (cc)

No Event of Loss or Event of Taking

As of the Closing Date, no material Event of Loss or material Event of Taking has occurred or is, to the Borrower’s Knowledge, threatened or pending.

 

  (dd)

Due Authorization

The execution, delivery and performance of the Finance Documents have been duly authorized by all necessary action on the part of each Obligor that is a party thereto.

 

  (ee)

No Indebtedness

In respect of each Obligor, it has no Indebtedness other than Indebtedness incurred in accordance with Section 12.14 (Limitation on Indebtedness).

 

  5.2

Repeated Representations and Warranties of the Obligors

Each Obligor makes the following representations and warranties to each Facility Lender. Unless otherwise indicated below, each such representation and warranty is made at the Closing Date, the date of each Advance and on the Project Completion Date:

 

-40-

Calcasieu Pass - Common Terms Agreement


  (a)

Organization

Each of the Obligors is a limited liability company duly organized validly existing and in good standing under the laws of the State of Delaware.

 

  (b)

Financial Statements

The financial statements of the Obligors most recently furnished to the Intercreditor Agent (whether pursuant to Section 4.1(h) (Conditions to Closing Date and Initial Advance – Financial Statements) or Section 10.1(a) (Accounting, Financial and Other Information)) present fairly in all material respects its financial condition as at the date thereof in accordance with GAAP (subject to normal year-end adjustments and except to the extent any notes to the financial statements would not be required thereunder) consistently applied.

 

  (c)

Power and Authority and Qualification

Each Obligor:

 

  (i)

has the power and authority to execute, deliver, perform and incur obligations under the Transaction Documents then in effect to which it is a party;

 

  (ii)

has the power and authority to make the assignment and grant the Lien and Security Interest granted in the Collateral pursuant to the Finance Documents;

 

  (iii)

has the power and authority for the execution, delivery and performance of each of the Transaction Documents to which it is a party, each of the Transaction Documents has been duly authorized by it, and (assuming the due execution and delivery by the counterparties to the Obligors thereto) each of the Transaction Documents to which it is a party is in full force and effect and constitutes a legal, valid and binding obligation of it, enforceable against it in accordance with its terms, except as limited by general principles of equity and bankruptcy, insolvency and similar laws; and

 

  (iv)

is qualified to do business and in good standing in every jurisdiction where its assets are located and wherever necessary to carry out its business and operations, except in jurisdictions where the failure to be so qualified or in good standing has not had, and could not be reasonably expected to have, a Material Adverse Effect.

 

-41-

Calcasieu Pass - Common Terms Agreement


  (d)

No Conflicts

 

  (i)

In respect of each of the Obligors, its Constitutional Documents do not conflict with or prevent execution or delivery or performance by it of the Transaction Documents then in effect to which it is a party;

 

  (ii)

neither (x) any material law applicable to it, or agreement to which it is a party, nor (y) any order, judgment or decree to which it or any of its assets are subject conflict in any material respect with, or prevent execution or delivery or performance by it of, the Transaction Documents then in effect to which it is a party or conflict in any material respect with its Constitutional Documents;

 

  (iii)

in respect of each of the Obligors, the Material Project Agreements then in effect to which it is a party do not conflict with or prevent execution or delivery or performance by it of the Finance Documents; and

 

  (iv)

the execution or delivery or performance by it of the Transaction Documents does not result in the creation or imposition of any Lien upon or with respect to any of its property or its assets now owned or hereafter acquired, other than Liens created under the Security Documents and other Permitted Liens.

 

  (e)

Regulatory Matters

 

  (i)

the FERC Order: (a) has been obtained by the Borrower with respect to the LNG Facility and by the Guarantor with respect to the TransCameron Pipeline, (b) is in full force and effect, and (c) is final and non-appealable;

 

  (ii)

the Obligors are in material compliance with the FERC Order, and the FERC order is free from conditions and requirements: (a) the compliance with which could reasonably be expected to have a Material Adverse Effect, or (b) that the applicable Obligor does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development except to the extent that failure to satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect;

 

  (iii)

each of the FTA Authorization and the Non-FTA Authorization: (a) has been obtained by the Borrower, (b) is in full force and effect, and (c) is final and non-appealable; and

 

  (iv)

the Borrower is in material compliance with each of the FTA Authorization and the Non-FTA Authorization, and each of the

 

-42-

Calcasieu Pass - Common Terms Agreement


  FTA Authorization and the Non-FTA Authorization is free from conditions and requirements: (a) the compliance with which could reasonably be expected to have a Material Adverse Effect, or (b) that the Borrower does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development except to the extent that failure to satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect.

 

  (f)

ERISA

In respect of each Obligor, it:

 

  (i)

does not sponsor or participate in, or have any obligation to contribute to, or any liability under, any Plan or Multiemployer Plan; and

 

  (ii)

no ERISA Event has occurred or is reasonably expected to occur.

 

  (g)

Title

 

  (i)

Except as otherwise permitted under the Finance Documents and other than with respect to real property (which is covered under clause (m) (Real Property) below), each Obligor owns good and valid title to all of its property and assets included in the Collateral, free and clear of all Liens other than Permitted Liens, and the Security Documents are effective to create a legal, valid and enforceable Lien on, and security interest in, all of the Collateral, and the Secured Parties have a first priority perfected security interest in the Collateral (subject to Permitted Liens); and

 

  (ii)

No previous assignment of, or security interest in, any Obligor’s right, title and interest in any of the Collateral has been made or granted by any Obligor that remains in effect or is otherwise effective other than pursuant to the Finance Documents to which the Obligor is a party or in respect of Permitted Liens.

 

  (h)

Subsidiaries

The Pledgor has no Subsidiaries other than the Obligors and none of the Obligors has any Subsidiaries.

 

  (i)

Investment Company Act (Obligors)

In respect of each Obligor, it is not, and after giving effect to the issuance of the Senior Debt and the application of proceeds of the Senior Debt in accordance with the provisions of the Finance Documents shall not be, an “investment company” required to be registered under the Investment Company Act of 1940.

 

-43-

Calcasieu Pass - Common Terms Agreement


  (j)

Margin Stock

 

  (i)

No part of the proceeds of any Advance shall be used for the purpose of buying or carrying any Margin Stock or to extend credit to others for such purpose; and

 

  (ii)

in respect of each Obligor, it is not engaged in the business of extending credit for the purpose of purchasing or carrying Margin Stock, and no proceeds of any Senior Debt shall be used for any purpose that violates, or would be inconsistent with, Regulations T, U or X of the Federal Reserve Board.

 

  (k)

Minimum Insurance

Except as otherwise approved by the Insurance Advisor, any Minimum Insurances applicable to each of the Obligors are in full force and effect if required to be in effect at such time.

 

  (l)

No Loan Facility Declared Default or Event of Default

No Unmatured Loan Facility Event of Default, Loan Facility Event of Default or Loan Facility Declared Default has occurred and is Continuing.

 

  (m)

Real Property

 

  (i)

The Obligors collectively have good, legal and valid real property interests in the applicable portion of the Site pursuant to the Real Property Documents, in each case as is necessary for the Development at the time this representation and warranty is made;

 

  (ii)

The Obligors do not have any real property interests other than with respect to the Site or except as set forth on Schedule 5.2(m) (Real Property Interests);

 

  (iii)

No action has been commenced or is pending to terminate, restate or replace any Lease; and

 

  (iv)

To the Knowledge of each Obligor, there is no default or existing condition which with the giving of notice or passage of time or both would cause a default under a Lease, and all rents due under the Leases have been timely paid in full.

 

-44-

Calcasieu Pass - Common Terms Agreement


  (n)

Intellectual Property

The Obligors collectively own or have obtained and hold in full force and effect all material Intellectual Property that is necessary for carrying out the Development except for such items which are not required in light of the applicable stage of Development, and reasonably believe that they shall be able to obtain such items that are not owned or have not been obtained as of the date on which this representation and warranty is made or deemed repeated on or prior to the relevant stage of Development, provided that any such items shall not contain any material condition or material requirement that they do not expect to be able to satisfy without cost that could reasonably be expected to have a Material Adverse Effect.

 

  (o)

Anti-Corruption Laws

 

  (i)

None of the Obligors, or any of their Affiliates, nor, to the Knowledge of any of these entities, the Sponsor or any of its Affiliates, any of their respective directors, officers, agents, employees or other persons acting on behalf of them, is aware of or has taken any action, directly or indirectly, that would result in a violation by such entity of the Applicable Anti-Corruption Laws, Anti-Terrorism and Money Laundering Laws or Sanctions applicable to such Person; and

 

  (ii)

The Obligors have instituted and maintain customary policies and procedures designed to ensure continued compliance therewith in all material respects.

 

  (p)

Collateral

The Collateral is subject to the perfected first priority Lien (subject only to Permitted Liens) established pursuant to the Security Documents.

 

  (q)

No Material Adverse Effect.

Since December 31, 2018, no event, circumstance or change has occurred (other than matters of a general economic nature) that has caused or evidenced, or could reasonably be expected to result in, a Material Adverse Effect.

 

  (r)

Accounts

Other than Authorized Investments held in accordance with the Common Security and Account Agreement, in respect of each Obligor, it does not have, and is not the beneficiary of, any bank account other than the Accounts and the Excluded Accounts.

 

-45-

Calcasieu Pass - Common Terms Agreement


  (s)

Material Project Agreements

 

  (i)

Each of the Material Project Agreements to which any Obligor is a party is in full force and effect to the Obligors’ Knowledge, and none of such Material Project Agreements has been terminated or otherwise amended, modified, supplemented, transferred, impaired or, to the Obligors’ Knowledge, assigned, except as permitted by the terms of the Finance Documents; and

 

  (ii)

no material default or event of default of any Obligor or, to the Knowledge of each Obligor, of any counterparty, have occurred and are continuing under any Material Project Agreement.

 

  (t)

Sufficiency of Funds

The Borrower reasonably believes that the Facility Debt Commitments and funds on deposit in the Construction Account (including any Equity Funding remaining on deposit in the Construction Account), Contingency Reserve Account and Permitted Finance Costs Reserve Account shall be sufficient to achieve the Project Completion Date by the Date Certain.

 

  (u)

Equity Interests and Ownership

The Equity Interests of each Obligor have been duly authorized and validly issued. There is no existing option, warrant, call, right, commitment or other agreement to which any Obligor is a party requiring, and there is no membership interest or other Equity Interests of Obligor outstanding which upon conversion or exchange would require, the issuance by any Obligor of any additional membership interests or other Equity Interests of any Obligor or other securities convertible into, exchangeable for or evidencing the right to subscribe for or purchase, a membership interest or other Equity Interests of any Obligor. The Obligors do not own any Equity Interests in any Person.

 

  (v)

Environmental Claims; Permit Notices

 

  (i)

Except as set forth in Schedule G (Disclosure Schedule) hereto, there is:

 

  (A)

no Environmental Claim now pending or, to the Knowledge of each Obligor, threatened against it or the Project Facilities, or expressly with respect to its Permits or the Development, that in each case could reasonably be expected to have a Material Adverse Effect; and

 

  (B)

no existing default by it under any applicable order, writ, injunction or decree of any Governmental Authority or arbitral tribunal with respect to Environmental Claims that

 

-46-

Calcasieu Pass - Common Terms Agreement


  could reasonably be expected to have a Material Adverse Effect; and

 

  (ii)

In respect of each Obligor, it has not received any notice from any Governmental Authority asserting that any information set forth in any application submitted by or on behalf of it in connection with any material Permit that has been obtained as of the date this representation is made or deemed repeated was inaccurate or incomplete at the time of submission that could reasonably be expected to have a Material Adverse Effect.

 

  (w)

Tax Status

In respect of each Obligor, it is a limited liability company that is treated as a partnership for U.S. federal income tax purposes or an entity disregarded for U.S. federal, state and local income tax purposes as separate from its owner and not an association taxable as a corporation, and neither the execution or delivery of any Transaction Document nor the consummation of any of the transactions contemplated thereby shall affect such status.

 

  (x)

Easements; Utilities; Services

All easements, leasehold and other real property interests, and all utility and other services, means of transportation, facilities, other materials and other related rights, that are necessary for the operation and maintenance of the Project Facilities, as currently conducted (and in light of the current status of Development), in accordance in all material respects with all applicable Government Rules and the Transaction Documents (including, to the extent applicable, gas, electrical, water and sewage services and facilities) are available to the applicable Obligor or, if not then available, are reasonably expected to be available to the applicable Obligor as and when needed for the operation and maintenance of the applicable Project Facility.

 

  (y)

Development

No other material contracts are necessary for the Development of the Project Facilities at their respective current stages of development other than the Material Project Agreements in effect.

 

  (z)

EEA Financial Institutions

As of the Closing Date, no Obligor is an EEA Financial Institution.

 

-47-

Calcasieu Pass - Common Terms Agreement


6.

INCURRENCE OF ADDITIONAL SENIOR DEBT

 

  6.1

Permitted Senior Debt

 

  (a)

The Borrower may from time to time enter into agreements to incur, and may incur, Senior Debt Obligations in addition to the Initial Senior Debt Obligations that, for so long as the Common Terms Agreement remains in effect in accordance with its terms, consist only of Working Capital Debt, and/or Replacement Senior Debt (and shall satisfy the requirements of this Article 6 (Incurrence of Additional Senior Debt) applicable to such category of Senior Debt).

 

  (b)

Each Senior Creditor Group Representative (on behalf of the Senior Creditors providing Additional Senior Debt) must accede to the Common Security and Account Agreement pursuant to, and in accordance with, the conditions set forth in Section 2.7 (Accession of Senior Creditor Group Representatives) of the Common Security and Account Agreement.

 

  (c)

Incurrence of Additional Senior Debt under one Section of this Article 6 (Incurrence of Additional Senior Debt) shall not preclude the incurrence of Additional Senior Debt under any other Section of this Article 6 (Incurrence of Additional Senior Debt), and the failure of the proposed Additional Senior Debt to meet the requirements of one Section of this Article 6 (Incurrence of Additional Senior Debt) shall not preclude the incurrence of such Additional Senior Debt if permitted under other Sections of this Article 6 (Incurrence of Additional Senior Debt).

 

  (d)

Additional Senior Debt under this Article 6 (Incurrence of Additional Senior Debt) may be incurred under this Agreement and/or any other Senior Debt Instrument.

 

  6.2

Working Capital Debt

 

  (a)

The Borrower may incur senior secured or unsecured Indebtedness (which, if secured, shall constitute Senior Debt) not exceeding an amount outstanding at any one time equal to the sum of:

 

  (i)

an aggregate principal amount not to exceed the amount of the Working Capital Facility as of the Closing Date; and

 

  (ii)

$255,000,000;

in each case outstanding in the aggregate at any one time under one or more working capital facilities (including, without limitation, the Working Capital Facility) (collectively, the “Working Capital Debt”) for working capital purposes (including the issuance of letters of credit from time to

 

-48-

Calcasieu Pass - Common Terms Agreement


time), as the case may be, so long as and provided that the Borrower certifies that:

 

  (A)

no Event of Default or Unmatured Event of Default:

 

  (1)

has occurred and is Continuing; or

 

  (2)

could reasonably be expected to occur after giving effect to the incurrence of the Working Capital Debt;

 

  (B)

any Senior Debt Instrument governing the Working Capital Debt shall require the Borrower to reduce the principal amount relating to any revolving Loans thereunder to $0 for a period of at least five (5) consecutive Business Days at least once per calendar year; provided that this requirement shall not apply to letters of credit outstanding or Loans outstanding as a result of a draw under a letter of credit; provided further that amounts may not be borrowed under any one Facility Agreement for Working Capital Debt in order to meet this requirement under any other Facility Agreement for Working Capital Debt (it being acknowledged and agreed that the foregoing shall not limit the utilization by the Borrower of other Indebtedness that is permitted to be incurred pursuant to Section 12.14 (Limitation on Indebtedness) for such purposes to the extent the terms and conditions of such Indebtedness permit such utilization); and

 

  (C)

the Intercreditor Agent has received, at least three (3) Business Days before the incurrence of any such Working Capital Debt, a certificate from the Borrower that:

 

  (1)

identifies each Senior Creditor Group Representative for, and each holder of, any such Working Capital Debt; and

 

  (2)

attaches a copy of each proposed Senior Debt Instrument relating to any such Working Capital Debt.

 

  (b)

Any provider of Working Capital Debt (or a Senior Creditor Group Representative on its behalf) that is secured shall accede as a Senior Creditor to the Common Security and Account Agreement, the Intercreditor Agreement and this Agreement, and shall share pari passu in the Collateral.

 

-49-

Calcasieu Pass - Common Terms Agreement


  6.3

Replacement Senior Debt

 

  (a)

At any time and from time to time, the Borrower may incur additional senior debt or enter into agreements with Persons who commit to provide additional senior secured or unsecured debt in order to prepay or repay Senior Debt and/or replace all or part of the Facility Debt Commitments under one or more Loans (“Replacement Senior Debt”), as the case may be, so long as and provided that the Borrower certifies that:

 

  (i)

the Replacement Senior Debt, taken as a whole:

 

  (A)

has a weighted average life no less than the then-remaining weighted average life of that of the Senior Debt or the Facility Debt Commitments being prepaid or replaced, taken as a whole;

 

  (B)

has a Final Maturity Date no earlier than the Senior Debt or the Facility Debt Commitments being prepaid or replaced; and

 

  (C)

may not be voluntarily prepaid or redeemed prior to having repaid the then-outstanding Term Loans in full and having cancelled all outstanding Term Loan Commitments;

 

  (ii)

the Replacement Senior Debt is incurred solely for the permitted prepayment, in whole or in part, of existing Senior Debt (and provisions, costs, prepayment premiums, fees or expenses associated with the Replacement Senior Debt or the prepaid Senior Debt, as applicable (including, without duplication, (A) any Hedging Termination Amount with respect to any Permitted Hedging Instrument subject to the refinancing with the proposed Replacement Senior Debt; (B) any amounts required to be deposited in a debt service reserve or similar reserve (or any interest during construction) account in connection with the issuance of such Replacement Senior Debt; and (C) any incremental carrying costs of such Replacement Senior Debt (including any increased interest during construction) associated with any such cancellation, prepayment or redemption, or incurred in connection with the proposed Replacement Senior Debt)) or the permitted replacement of existing unutilized commitments of a Senior Creditor Group (or, within a Senior Creditor Group, of any Facility Lender);

 

  (iii)

the aggregate principal amount of Replacement Senior Debt incurred or committed and then available does not exceed the aggregate amount of the Senior Debt or the Facility Debt Commitments prepaid or replaced, together with any premiums,

 

-50-

Calcasieu Pass - Common Terms Agreement


costs, fees or expenses associated with the Replacement Senior Debt (including those described in sub-clause (ii) above and clause (b) below);

 

  (iv)

the Borrower will have demonstrated by delivery of an updated Base Case Forecast (prepared in accordance with the Base Case Sizing Criteria) that the incurrence of the Replacement Senior Debt shall not result in a Fixed Projected DSCR of less than 1.40:1 commencing on the first CTA Payment Date following such prepayment for each twelve (12) month period thereafter (including any stub period) through the Qualifying Term of the Qualifying LNG SPAs then in effect (with such ratio being calculated on a pro forma basis giving effect to the incurrence of the Replacement Senior Debt and the prepayment or repayment of the existing Senior Debt or cancellation of the Facility Debt Commitments);

 

  (v)

the Replacement Senior Debt is ranked pari passu and is treated pro rata in all respects with Senior Debt, and does not benefit from any security or guarantee from the Collateral Parties that is in addition to any security or guarantee from such Persons provided in respect of any then-outstanding Senior Debt (including any Senior Debt Commitments thereunder) unless such security or guarantee is provided for the equal and ratable benefit of each Senior Creditor;

 

  (vi)

the Replacement Senior Debt does not benefit from any material covenants or terms that are materially more restrictive on the Obligors than those included in this Agreement unless such covenants or terms are provided for the benefit of all Facility Lenders;

 

  (vii)

simultaneously with the incurrence of any Replacement Senior Debt that occurs on or after the date by which the Borrower is required to fund the Senior Facilities Debt Service Reserve Account in accordance with Section 4.5(i) (Deposits and Withdrawals – Senior Facilities Debt Service Reserve Account) of the Common Security and Account Agreement, the Borrower shall use a portion of the proceeds of such Replacement Senior Debt to fund any increase in the then-applicable Senior Facilities Reserve Amount or, if such Replacement Senior Debt does not constitute Facility Debt Obligations, fund any Additional Debt Service Reserve Account opened by the Borrower in accordance with the Common Security and Account Agreement that was established for such Replacement Senior Debt in an amount as required by such Replacement Senior Debt; and

 

-51-

Calcasieu Pass - Common Terms Agreement


  (viii)

the Intercreditor Agent has received (A) at least three (3) Business Days prior to the incurrence of such Replacement Senior Debt, (1) a notice describing the then-anticipated principal terms and conditions of the proposed Replacement Senior Debt (other than, in the case of Replacement Senior Debt comprised of Senior Notes, the pricing and amortization schedule of such Senior Notes, which shall be provided when they become available) and (2) the substantially agreed forms of the finance documents relating to any proposed Replacement Senior Debt (other than in the case of Replacement Senior Debt comprised of Senior Notes) and (B) on the date of the incurrence of such Replacement Senior Debt, (1) an updated notice describing the final principal terms and conditions of the Replacement Senior Debt (including, in the case of Replacement Senior Debt comprised of Senior Notes, the pricing and amortization schedule of such Senior Notes). (2) copies of the executed finance documents relating to the Replacement Senior Debt and (3) an officer’s certificate of the Obligors certifying to the matters set forth in clauses (i)-(vii) above;

provided, in each case, that no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing or could reasonably be expected to occur after giving effect to the incurrence of the Replacement Senior Debt. Any provider of Replacement Senior Debt (or a Senior Creditor Group Representative on its behalf) shall accede as a Senior Creditor to the Common Security and Account Agreement and, if a Facility Lender, the Intercreditor Agreement and this Agreement, and shall share pari passu in the Collateral.

 

  (b)

Within 30 days after the first Advance of any Replacement Senior Debt, the Borrower shall pay, from the proceeds of the Replacement Senior Debt or other cash flow available for such purpose, any Breakage Costs and/or other amounts required to be paid in accordance with Section 3.6 (Prepayment Fees and Breakage Costs) and the applicable Facility Agreement with respect to the Facility Debt Commitments being replaced.

 

7.

PERMITTED DEVELOPMENT EXPENDITURES/EXPANSIONS

 

  7.1

Permitted Development Expenditures

 

  (a)

The Obligors shall not make any Development Expenditures that do not qualify as Permitted Development Expenditures. Assets or property built or acquired with Development Expenditures shall constitute Collateral except as provided in the Security Documents.

 

  (b)

For the avoidance of doubt, (i) Permitted Development Expenditures may be made prior to the Project Completion Date to the extent permitted under Article 9 (Material Construction Contracts) and (ii) Permitted

 

-52-

Calcasieu Pass - Common Terms Agreement


 

Development Expenditures may also be made in relation to an Expansion to the extent permitted under Section 7.2 (Expansion Contracts).

 

  7.2

Expansion Contracts

 

  (a)

The Obligors shall not enter into a construction contract or contracts with respect to the development of any mixed refrigerant liquefaction blocks, modules and supporting facilities in addition to the LNG Facilities, and related loading, transportation and storage facilities, in addition to the Development then in operation or under construction that contain obligations and liabilities which, in the aggregate, are in excess of $50 million (an “Expansion”) without the prior consent of the Intercreditor Agent acting at the instruction of the Requisite Intercreditor Parties; provided that without such consent the Obligors may:

 

  (i)

conduct front-end engineering, development and design work using Equity Funding not otherwise committed to other expenditures for the Development;

 

  (ii)

prepare and submit applications for Permits related to any such Expansion; and

 

  (iii)

undertake pre-construction activities and early works activities associated with an Expansion;

provided that such activities shall be funded from (A) Equity Funding not otherwise committed to other expenditures for the Development, or (B) Retained Excess Cash Flow, in the case of each of the foregoing sub-clauses (A) and (B), in each case as expressly permitted under the Finance Documents and which use for the contemplated development could not reasonably be expected to have a Material Adverse Effect.

 

8.

LNG SPA COVENANTS

 

  8.1

LNG SPA Maintenance

 

  (a)

The Borrower shall maintain Qualifying LNG SPAs providing for commitments to purchase LNG in quantities at least equal to the Base Committed Quantity for a Qualifying Term unless one or more of such Qualifying LNG SPAs has terminated, in which case the Borrower shall enter into a replacement Qualifying LNG SPA within 90 days following such termination to the extent necessary to meet the Base Committed Quantity; provided that the Borrower shall have a further 90 days to enter into such a replacement Qualifying LNG SPA if the following two conditions are met:

 

-53-

Calcasieu Pass - Common Terms Agreement


  (i)

the Borrower intends to replace such terminated LNG SPA with an LNG SPA that would be a Qualifying LNG SPA that causes the Obligors to meet the Base Committed Quantity and is diligently pursuing such replacement; and

 

  (ii)

the termination of such Qualifying LNG SPA could not reasonably be expected to result in a Material Adverse Effect;

and the Intercreditor Agent has received a certification from the Borrower confirming that each such condition above has been met prior to the expiration of the initial 90 day period together with documentation reasonably supporting its certification, which may include, to the extent relevant and applicable, a description of the plans being undertaken and expected schedule for replacement of the terminated LNG SPA (although commercially sensitive information may be omitted), any measures being taken by the Borrower to address the underlying cause of the termination to the extent relevant to the termination and the replacement process, any interim cash flow mitigation measures being taken by the Borrower (including sales of spot cargoes) and the impact on the Borrower’s projected Cash Flow during the subsequent cure period.

For the avoidance of doubt, the Qualifying LNG SPAs required to be maintained in accordance with the provisions of this Section 8.1 (LNG SPA Maintenance) are referred to as “Required LNG SPAs”.

 

  (b)

A “Qualifying LNG SPA” includes each of the Initial LNG SPAs, any LNG SPA entered into for a Qualifying Term in accordance with Section 8.4 (Sale of Supplemental Quantity), and any other LNG SPA that meets each of the following conditions:

 

  (i)

such LNG SPA is entered into for a Qualifying Term with:

 

  (A)

an Investment Grade LNG Buyer (or guaranteed by an Investment Grade entity);

 

  (B)

in the case of any LNG SPA that is a replacement of an LNG SPA referenced in clauses (a) or (d) of the definition of “Initial LNG SPAs”, (i) an Investment Grade LNG Buyer (or guaranteed by an Investment Grade entity) or (ii) an entity with consolidated net tangible assets of at least $15 billion (or guaranteed by an entity with such consolidated net tangible assets);

 

  (C)

in the case of any LNG SPA entered into in accordance with Section 8.4 (Sale of Supplemental Quantity) or any LNG SPA that is a replacement of an LNG SPA referenced in clauses (b), (c), (e) or (f) of the definition of “Initial

 

-54-

Calcasieu Pass - Common Terms Agreement


 

LNG SPAs”, so long as the Borrower has other Qualifying LNG SPAs for at least 6.0 MTPA of ACQ with counterparties that are an Investment Grade LNG Buyer (or guaranteed by an Investment Grade entity), an entity with consolidated net tangible assets of at least $3 billion per 1.0 MTPA of ACQ (or guaranteed by an entity with such consolidated net tangible assets); or

 

  (D)

any other entity approved by the Intercreditor Agent;

 

  (ii)

delivery of LNG under such LNG SPA is on an FOB basis;

 

  (iii)

the Borrower has delivered to the Intercreditor Agent notice of the proposed terms of such LNG SPA; and

 

  (A)

 

  (1)

such terms are consistent, in all material respects, with (and not materially less favorable in the aggregate to the interests of the Borrower than) those set forth in any Qualifying LNG SPA then in effect; or

 

  (2)

the Intercreditor Agent confirms that the Requisite Intercreditor Parties, after consultation with the Market Consultant, are reasonably satisfied with the terms of such LNG SPA, including its conformity to Market Terms;

 

  (iv)

the execution of such LNG SPA and performance by the Borrower of its obligations under such LNG SPA shall not result in a breach of any Qualifying LNG SPA then in effect, or any Required Export Authorization then in effect and no additional Required Export Authorizations are necessary in connection with the execution of such LNG SPA; and

 

  (v)

the Borrower has delivered to the Intercreditor Agent a certificate certifying to the matters set forth in clauses (i), (ii), (iii)(A)(1) (if applicable) and (iv) above.

 

  8.2

LNG SPA Mandatory Prepayment

 

  (a)

The Borrower shall be required to make a mandatory prepayment (an “LNG SPA Mandatory Prepayment”) if either of the events set forth below occurs (each, an “LNG SPA Prepayment Event”):

 

-55-

Calcasieu Pass - Common Terms Agreement


  (i)

the Borrower breaches the covenant in Section 8.1 (LNG SPA Maintenance) (taking into account the period set forth therein to replace the relevant LNG SPA); or

 

  (ii)

with respect to any Required LNG SPA, a Required Export Authorization becomes Impaired and the Borrower does not:

 

  (A)

provide a reasonable remediation plan (setting forth in reasonable detail proposed steps to reinstate the Required Export Authorization or to modify its LNG SPA arrangements, such as through lawful diversions by the counterparty thereto and/or alternative delivery or sale arrangements, such that such Impaired Export Authorization is no longer a Required Export Authorization with respect to any or all such Required LNG SPAs (each such item, an “Export Authorization Remediation”)) within 30 days following such occurrence;

 

  (B)

diligently pursue such Export Authorization Remediation; or

 

  (C)

cause such Export Authorization Remediation to take effect within 90 days following the occurrence of the Impairment; provided that the Borrower shall have a further 90 days to effect an Export Authorization Remediation if the following two conditions are met:

 

  (1)

the Borrower is diligently pursuing its plan for the Export Authorization Remediation; and

 

  (2)

the Impairment of the Required Export Authorization of such Required LNG SPA could not reasonably be expected to result in a Material Adverse Effect during such subsequent cure period;

and the Intercreditor Agent has received a certification from the Borrower confirming that each such condition above has been met prior to the expiration of the initial 90 day period together with documentation reasonably supporting its certification, which may include, to the extent relevant and applicable, a description of the plans being undertaken for the Export Authorization Remediation (although commercially sensitive information may be omitted), any measures being taken by the Borrower to address the underlying cause of the Impairment to the extent relevant to the Impairment and Export Authorization Remediation, any legal measures being undertaken to

 

-56-

Calcasieu Pass - Common Terms Agreement


reverse the Impairment, any interim cash flow mitigation measures being taken by the Borrower (including sales of spot cargoes), any modification to LNG SPA arrangements such that the Impaired Export Authorization is no longer a Required Export Authorization with respect to any or all such Required LNG SPAs, and the impact on the Borrower’s projected Cash Flow during the subsequent cure period, and the Intercreditor Agent (acting on the instructions of the Requisite Intercreditor Parties), acting reasonably, has not objected to such certification within 30 days following delivery thereof.

 

  (b)

The amount of the Senior Debt (which shall not extend to any Working Capital Debt unless only Working Capital Debt remains outstanding) that the Borrower shall repay and the amount of undrawn Facility Debt Commitments (which shall not include any Working Capital Debt unless only Working Capital Debt remains outstanding) that the Borrower shall cancel upon the occurrence of any LNG SPA Prepayment Event shall be an amount equal to:

 

  (i)

the aggregate principal amount of Senior Debt then outstanding plus the aggregate principal amount of undrawn Facility Debt Commitments; less

 

  (ii)

the maximum amount of Senior Debt that can remain outstanding consistent with the Base Case Sizing Criteria based on the Base Case Forecast and updated to take into account each Qualifying LNG SPA then in full force and effect (after giving effect to the LNG SPA Prepayment Event) and including any new Qualifying LNG SPAs entered into by the Borrower to replace an LNG SPA the termination of which triggered the LNG SPA Prepayment Event.

The Borrower shall provide to the Intercreditor Agent reasonable documentary support to show the amount of Senior Debt to be repaid and Senior Debt Commitments to be cancelled, including the Base Case Sizing Criteria and the updated Base Case Forecast and, to the extent appropriate, the Required LNG SPAs then in effect and reasonable background information regarding Required Export Authorizations with respect to such Required LNG SPAs and supporting the designation of such Export Authorizations as Required Export Authorizations with respect to such Required LNG SPAs.

 

  (c)

In making the prepayment and cancellation described in clause (b) above, the Borrower shall first repay the aggregate principal amount of Senior Debt Obligations then outstanding to the extent required under this Section 8.2 (LNG SPA Mandatory Prepayment) or until there are no more Senior

 

-57-

Calcasieu Pass - Common Terms Agreement


Debt Obligations outstanding and if this has not resulted in a prepayment of the amount required to satisfy the test in clause (b) above, shall second cancel the aggregate principal amount of Facility Debt Commitments to the extent required under this Section 8.2 (LNG SPA Mandatory Prepayment). The prepayment and cancellation made pursuant to this Section 8.2 (LNG SPA Mandatory Prepayment) shall be required to be made by the earliest of (i) the 30th day following the termination of the cure period applicable thereto, (ii) the next Quarterly Payment Date if such date is more than 10 Business Days following the termination of the cure period applicable thereto and (iii) the 10th Business Day following the termination of the cure period applicable thereto if the next Quarterly Payment Date is less than 10 Business Days following the termination of the cure period applicable thereto.

 

  (d)

Upon completion of the prepayment of Senior Debt and cancellation of Facility Debt Commitments as and to the extent required by clause (b) and (c) above, the LNG SPA Prepayment Event and underlying breach of Section 8.1 (LNG SPA Maintenance) or Impairment triggering that LNG SPA Prepayment Event shall no longer be continuing under the Finance Documents in so far as the same set of events, facts or circumstances that caused such breach, Impairment and mandatory prepayment are concerned, but without prejudice to the Borrower’s obligations under Section 8.1 (LNG SPA Maintenance) and Section 8.2 (LNG SPA Mandatory Prepayment) with respect to any other event, fact or circumstance.

 

  8.3

Amendment of LNG SPAs

The Borrower shall not agree to:

 

  (a)

any amendment or modification of the price or quantity provisions of any Qualifying LNG SPA:

 

  (i)

if such amendment or modification results in a breach of Section 8.1 (LNG SPA Maintenance); or

 

  (ii)

unless after giving effect to such amendment or modification, the Fixed Projected DSCR starting from the CTA Payment Date for the repayment of principal following the date of such amendment or modification and for each calendar year thereafter through the Qualifying Term of the Qualifying LNG SPAs then in effect is at least 1.50:1.00;

 

  (b)

any amendment or modification of any Qualifying LNG SPA that:

 

  (i)

could reasonably be expected to have a Material Adverse Effect;

 

-58-

Calcasieu Pass - Common Terms Agreement


  (ii)

would not be on Market Terms; or

 

  (iii)

would otherwise violate or conflict with the terms of the Finance Documents;

 

  (c)

any material waiver, amendment or modification of the governing law, choice of forum, responsibility for shipping (i.e., FOB or delivery ex- ship/delivered-at-terminal basis), term (other than an increase), or guarantee or credit support provisions (other than an increase or improvement) of any Qualifying LNG SPA, in each case if within 60 days following notice of such proposed amendment or modification, the Intercreditor Agent notifies the Borrower in writing of its objection to such proposed amendment or modification; or

 

  (d)

any amendment or modification of the material elements of the structure or components of the pricing formula or the methodology of calculating the Contract Sales Price or any material term defining the “take-or-pay” obligations of any Qualifying LNG SPA (other than any increase or improvement thereof), in each case, if within 60 days following notice of such proposed amendment or modification, the Intercreditor Agent notifies the Borrower in writing of its objection to such proposed amendment or modification.

 

  8.4

Sale of Supplemental Quantity

 

  (a)

The Borrower shall be permitted to enter into LNG SPAs in respect of all or any portion of the Supplemental Quantity, which LNG SPAs may be of any duration, on any terms and to buyers of any credit quality; provided that:

 

  (i)

the Required LNG SPAs are then in full force and effect;

 

  (ii)

either (A) such LNG SPA has a term that is less than 3 years or (B) such LNG SPA is entered into with (1) an Initial LNG Buyer, (2) an Investment Grade LNG Buyer (or guaranteed by an Investment Grade entity), (3) an entity with consolidated net tangible assets of at least $3 billion per 1.0 MTPA of ACQ (or guaranteed by an entity with such consolidated net tangible assets) or (4) any other entity approved by the Intercreditor Agent;

 

  (iii)

each buyer thereunder is instructed to pay the contract sales price to the Pre-Completion Revenues Account or the Revenue Account as required by Section 8.6 (Payment of LNG Sales Proceeds);

 

  (iv)

the performance by the Borrower of its obligations under such LNG SPAs could not reasonably be expected to have a material adverse effect on the ability of the Borrower to perform its obligations under the Required LNG SPAs;

 

-59-

Calcasieu Pass - Common Terms Agreement


  (v)

such LNG SPA is on Market Terms;

 

  (vi)

the entry into and the terms of such LNG SPA shall not result in a breach or default of any Required LNG SPA then in effect or the Impairment of any then-required material Permit; and

 

  (vii)

delivery of LNG under such LNG SPA is on an FOB basis.

 

  8.5

Sale of Pre-Commercial Quantities

 

  (a)

The Borrower shall be permitted to enter into LNG SPAs in respect of any LNG produced or to be produced by the LNG Facility prior to the Commercial Operation Date, which LNG SPAs may be of any duration, on any terms and to buyers of any credit quality; provided that:

 

  (i)

the Required LNG SPAs are then in full force and effect;

 

  (ii)

such LNG SPA has a term that ends no later than the day immediately preceding each of the Commercial Operation Date (as defined in each Initial LNG SPA);

 

  (iii)

each buyer thereunder is instructed to pay the contract sales price to the Pre-Completion Revenues Account as required by Section 8.6 (Payment of LNG Sales Proceeds);

 

  (iv)

the performance by the Borrower of its obligations under such LNG SPAs could not reasonably be expected to have a material adverse effect on the ability of the Borrower to perform its obligations under the Required LNG SPAs;

 

  (v)

the entry into and the terms of such LNG SPA shall not result in a breach or default of any Required LNG SPA then in effect or the Impairment of any then-required material Permit; and

 

  (vi)

delivery of LNG under such LNG SPA is on an FOB basis.

 

  8.6

Payment of LNG Sales Proceeds

The Borrower shall irrevocably instruct each LNG Buyer to pay the proceeds of sales of LNG under its LNG SPAs directly into:

 

  (a)

the Pre-Completion Revenues Account for any payments made prior to the Project Completion Date; and

 

-60-

Calcasieu Pass - Common Terms Agreement


  (b)

the Revenue Account for any payments made on or after the Project Completion Date.

 

9.

MATERIAL CONSTRUCTION CONTRACTS

 

  9.1

Change Orders

Other than with respect to any Change Order specified in Schedule I (Change Orders) hereto, the Obligors shall not agree to:

 

  (a)

initiate or consent to (without the consent of the Intercreditor Agent acting in consultation with and in reliance on the applicable certificates from the Independent Engineer) any Change Order that:

 

  (i)

increases the contract price of a Material Construction Contract as of the Closing Date or increases the aggregate anticipated Project Costs of the Project Facilities in excess of the costs contemplated by the Construction Budget and Schedule; provided that: the Obligors may, without the consent of the Intercreditor Agent (or delivery of any certificate from the Independent Engineer) and subject to sub-clauses (ii) through (vii) below, enter into any Change Order under any Material Project Agreement or other contract if:

 

  (A)

the amount of any such Change Order is less than $50 million individually and the aggregate of all such Change Orders or payments with respect to the Material Project Agreements and/or other contracts (taken together), is less than $100 million collectively; and

 

  (B)

(I) such Change Order does not, individually or when taken together with all other Change Orders, exceed the Contingency Reserve Amount (as such amount is replenished with any deposits into the Contingency Reserve Account by funds transferred in accordance with Section 4.5(b)(ii)(C) (Deposits and Withdrawals – Pre-Completion Revenues Account) of the Common Security and Account Agreement); or (II) if the Change Orders are paid for in connection with any reallocation of aggregate contingency or application of cost savings from any line item in the Construction Budget and Schedule, then the Obligors may, without the consent of the Intercreditor Agent and subject to sub-clauses (ii) through (vii) below, enter into a Change Order to make payment of any claim under such Material Project Agreements and/or other contracts;

 

-61-

Calcasieu Pass - Common Terms Agreement


  (ii)

modifies any credit support requirements, warranty, Performance Liquidated Damages or Delay Liquidated Damages or Schedule Bonus under any Material Project Agreement in a manner that is materially adverse to the Obligors or the Secured Parties;

 

  (iii)

changes the scope of work or performance testing standards under any Material Project Agreement in a manner materially adverse to the Obligors;

 

  (iv)

extends any of the LPS1 Substantial Completion Deadline, the LPS2 Substantial Completion Deadline or the LPS3 Substantial Completion Deadline (each as defined in the EPC Contract) by more than 60 days, unless:

 

  (A)

the Independent Engineer certifies that the substantial completion of the applicable LNG Production System (each as defined in the EPC Contract) is reasonably likely to occur within an additional 60 days;

 

  (B)

the Borrower is diligently working to achieve substantial completion of such block or module within such additional 60-day period; and

 

  (C)

the Facility Substantial Completion Deadline (as defined in the EPC Contract) could not be reasonably expected to be adversely affected.

 

  (v)

delays the Facility Substantial Completion Deadline (as defined in the EPC Contract);

 

  (vi)

results in the revocation or adverse modification of any material Permit; or

 

  (vii)

could reasonably be expected to result in a Material Adverse Effect.

 

  9.2

UOP Pre-Treatment Systems

No Obligor shall agree to any Change Order that modifies the basis of design of the pre-treatment systems supplied by UOP pursuant to the Pretreatment Contract that would require subsequent changes to the basis of design for the equipment delivered under either the LTS Purchase Order or the PIS Purchase Order unless the Borrower delivers together with such Change Order a written confirmation from BHGE that such modification does not affect any performance guarantee (including any minimum performance guarantee or unconditional performance obligation under either the LTS Purchase Order or the PIS Purchase Order), in which event such Change Order shall be permitted (subject to Section 9.1 (Change Orders)).

 

-62-

Calcasieu Pass - Common Terms Agreement


10.

REPORTING BY THE BORROWER

The Borrower shall be bound by the following reporting obligations:

 

  10.1

Accounting, Financial and Other Information

The Borrower shall:

 

  (a)

furnish to the Intercreditor Agent:

 

  (i)

within 60 days following the end of the first three fiscal quarters of each fiscal year, beginning with the fiscal quarter ending September 30, 2019, consolidating unaudited statements of income and cash flows of the Obligors for such period and for the period from the beginning of the respective fiscal year to the end of such period and the related balance sheet as at the end of such period, setting forth in each case in comparative form the corresponding figures for the corresponding period in the preceding fiscal year; and

 

  (ii)

within 120 days after the end of each fiscal year beginning with the fiscal year ending December 31, 2019, the Obligors’ consolidating annual financial statements, audited by the Independent Accountants, accompanied by an audit opinion of such Independent Accountants to the effect that such financial statements fairly present, in all material respects, the financial position and results of operations and cash flows of the Obligors in accordance with GAAP (which opinion shall not be subject to any “going concern” qualification); and

 

  (b)

concurrently with the delivery of the financial statements pursuant to clause (a) above, furnish:

 

  (i)

a certificate executed by an Authorized Officer of each of the Obligors certifying that such financial statements fairly present in all material respects the financial condition and results of operations of the Obligors on the dates and for the periods indicated in accordance with GAAP, subject, in the case of a quarterly financial statement, to the absence of notes and normal year-end audit adjustments;

 

-63-

Calcasieu Pass - Common Terms Agreement


  (ii)

a certificate executed by an Authorized Officer of the Borrower certifying that no Unmatured Loan Facility Event of Default or Loan Facility Event of Default exists as of the date of such certificate or, if any Unmatured Loan Facility Event of Default or Loan Facility Event of Default exists, specifying the nature and extent thereof; and

 

  (iii)

a written summary of Gas hedges entered into by any Obligor, detailing aggregate outstanding contract volumes, price ranges of such Gas hedges and the associated value at risk with respect to such Gas hedges for the Development as of the end of each quarter.

 

  (c)

Upon a reasonable request from any Facility Agent, furnish (i) any change in the information provided in the Beneficial Ownership Certification that would result in a change to the list of beneficial owners identified in sections (i) or (ii) of such certification and (ii) any documents that are required in order for each Facility Lender to carry out all necessary “know your customer” or similar requirements, including those reasonably required to ensure compliance with anti-money laundering procedures (including the USA Patriot Act) in its relevant jurisdiction, in each case under this clause (ii) to the extent not otherwise delivered to the relevant Finance Party at or prior to the Closing Date or subsequently delivered.

 

  10.2

Quarterly Historical DSCR Certificate

No later than fifteen (15) Business Days following the last day of each fiscal quarter following the First Repayment Date, the Borrower shall calculate and deliver to the Collateral Agent its calculation of the Historical DSCR.

 

  10.3

Notices

The Borrower shall provide prompt written notice to the Intercreditor Agent and each Facility Agent upon any Obligor having Knowledge of any:

 

  (a)

Unmatured Loan Facility Event of Default or Loan Facility Event of Default and any action being taken or proposed to be taken with respect thereto;

 

  (b)

damage, loss or destruction of all or a material portion of the Project Facilities or an Event of Taking in excess of $75 million in value or any series of such events or circumstances during any 12-month period in excess of $250 million in value in the aggregate, or the initiation of any insurance claim proceedings with respect to any such event;

 

  (c)

claim, Environmental Claim, suit, arbitration, litigation or similar proceeding pending or threatened in writing (i) with respect to or against the Development or the Collateral Parties (A) in which the amount involved is in excess of $250 million; (B) that could reasonably be excepted to have a Material Adverse Effect; or (C) involving injunctive or

 

-64-

Calcasieu Pass - Common Terms Agreement


 

declaratory relief; or (ii) involving any other party to any of the Material Project Agreements, in each case, which could reasonably be expected to have a Material Adverse Effect or result in a Loan Facility Event of Default, and, in each case, copies or summaries thereof and a description of any action being taken or proposed to be taken with respect thereto;

 

  (d)

dispute, litigation, investigation or proceeding between any Governmental Authority and a Collateral Party involving the Development in which the amount involved is in excess of $250 million or that could reasonably be expected to have a Material Adverse Effect, in each case, including a reasonable summary thereof;

 

  (e)

force majeure event in respect of the Development reasonably expected to exceed 30 consecutive days, including its expected duration and any action being taken or proposed to be taken with respect thereto;

 

  (f)

cessation of activities by any of the Construction Contractors, the Manager or applicable Operator related to the Development that is not otherwise reflected in the Construction Budget and Schedule and could reasonably be expected to exceed 60 consecutive days;

 

  (g)

unless previously notified pursuant to another provision in the Finance Documents, event, occurrence or circumstance that could reasonably be expected to cause:

 

  (i)

an increase of more than an aggregate of $100 million in Project Costs which has not been previously notified pursuant to Article 9 (Material Construction Contracts); or

 

  (ii)

Operation and Maintenance Expenses to exceed the amount budgeted therefor by 10% or more in the aggregate per annum or 20% per line item per annum, calculated as set forth in Section 12.3 (Project Construction; Maintenance of Properties);

 

  (h)

an ERISA Event or any other event or circumstance that could reasonably be expected to result in material liability to any Collateral Party under ERISA or under the Code with respect to any Plan or Multiemployer Plan;

 

  (i)

material modifications to any Senior Debt Instrument, together with copies of such modifications;

 

  (j)

material Permit obtained by a Collateral Party or for the benefit of the Development not previously delivered, when available to the Collateral Party, together with a copy of such Permit;

 

-65-

Calcasieu Pass - Common Terms Agreement


  (k)

material written statement or report received by a Collateral Party from the Operators pursuant to the O&M Agreements together with a copy of such statement or report;

 

  (l)

Impairment of any material Permit;

 

  (m)

notice to be delivered or received pursuant to any Material Project Agreement that is material to the Development, together with a copy thereof;

 

  (n)

prepayment of Senior Debt resulting in a Hedging Excess Amount, which notice shall certify:

 

  (i)

the total amount of such Hedging Excess Amount; and

 

  (ii)

the allocation of the Hedging Excess Amount across the applicable Permitted Hedging Instruments in respect of which the hedged amount is to be reduced;

 

  (o)

execution of material agreements entered into by a Obligor after the Closing Date, which notices shall be provided at least five (5) Business Days prior to the execution of any such agreement or earlier if expressly specified herein;

 

  (p)

when available, copies of material agreements entered into by a Obligor after the Closing Date (not already delivered to the Intercreditor Agent pursuant to another provision of the Finance Documents);

 

  (q)

event (other than any event specified above) that could reasonably be expected to have a Material Adverse Effect; and

 

  (r)

on an annual basis, a copy of the Composite ADP (as such term is defined in each Initial LNG SPA) provided by the Borrower under the Initial LNG SPAs; and

 

  (s)

any failure by the Borrower to deliver at least 50% of the LNG required to be made available by the Borrower in accordance with the applicable delivery schedule under any Qualifying LNG SPA in any month, and any action taken or proposed to be taken in connection therewith.

 

  10.4

Construction Reports

 

  (a)

Prior to the Project Completion Date, as soon as available and in any event:

 

  (i)

within 30 days following the end of each month (or if such date is not a Business Day, the following Business Day), the Borrower shall deliver to the Intercreditor Agent and Independent Engineer

 

-66-

Calcasieu Pass - Common Terms Agreement


 

each of the construction reports provided to the Obligors under the Material Construction Contracts during the prior month; and

 

  (ii)

by the last Business Day of the month following the month in sub-clause (i) above, a monthly construction report from the Independent Engineer regarding the Project Facilities; provided that the failure to provide such construction report pursuant to this sub-clause (ii) by the last Business Day following the end of each such month (other than as a result of an act or omission by the Borrower or its Affiliates) shall not constitute an Unmatured Loan Facility Event of Default or a Loan Facility Event of Default.

 

  (b)

The full monthly construction report shall set forth the following in reasonable detail:

 

  (i)

estimated dates on which the LPS1 Substantial Completion Date, the LPS2 Substantial Completion Date, the LPS3 Substantial Completion Date (each as defined in the EPC Contract), the Commercial Operation Date and the Project Completion Date shall be achieved;

 

  (ii)

the Borrower’s then-current estimate of anticipated Project Costs through the Project Completion Date as compared to the Construction Budget and Schedule at Closing Date, and in the event of a material variance, the reasons therefor;

 

  (iii)

any event or circumstance the occurrence of which the Borrower is aware that could reasonably be expected to:

 

  (A)

increase the total Project Costs materially above those set forth in the Construction Budget and Schedule;

 

  (B)

delay Project Completion Date beyond the Date Certain (as reasonably anticipated by the Borrower as of such time); or

 

  (C)

have a Material Adverse Effect;

 

  (iv)

if Project Completion Date is not anticipated to occur on or before the Date Certain, the reasons therefor (and a schedule recovery plan);

 

  (v)

the status of construction of the Project Facilities, including progress under each Material Construction Contract (and a description of any material defects or deficiencies with respect thereto), and the proposed construction schedule for the following 90 days of the Project Facilities, including a description, as compared with the Construction Budget and Schedule, of the status

 

-67-

Calcasieu Pass - Common Terms Agreement


 

of engineering, procurement, construction, commissioning and testing;

 

  (vi)

the status of construction of the TransCameron Pipeline;

 

  (vii)

the status of construction of the interconnection facilities being constructed in accordance with each of the Gas Transportation Agreements;

 

  (viii)

a copy of any filing made by an Obligor with:

 

  (A)

FERC with respect to the Development; or

 

  (B)

the DOE with respect to the export of LNG from the Project Facilities,

 

 

(except in each case such filings as are routine or ministerial in nature), which copy may be provided by means of a link to the website where such filing is posted;

 

  (ix)

a copy of any filing made by any Person other than an Obligor with:

 

  (A)

FERC with respect to the Development in any proceeding in which an Obligor is the captioned party or respondent; or

 

  (B)

the DOE with respect to the export of LNG from the Project Facilities in any proceeding in which an Obligor is the captioned party or respondent,

 

 

(except in each case such filings as are routine or ministerial in nature), which copy may be provided by means of a link to the website where such filing is posted;

 

  (x)

updates to Schedule F (Material Permits) hereto reflecting the status of any material Permits necessary for the Development, including the dates of applications submitted or to be submitted and the anticipated dates of actions by Governmental Authorities with respect to such Permits; and

 

  (xi)

a listing of reportable environmental, health and safety incidents, any material unplanned related impacts, events, accidents or issues, and any material noncompliance with Environmental Laws that occurred during the report period.

 

-68-

Calcasieu Pass - Common Terms Agreement


  10.5

Operating Budget

 

  (a)

No less than 45 days prior to the earlier of (x) the Commercial Operation Date and (y) the LPS1 Substantial Completion Date, in each case, as reasonably estimated by the Borrower as of the date such report is provided, and no less than 45 days prior to the beginning of each calendar year thereafter, the Obligors shall prepare a proposed operating plan and budget setting forth in reasonable detail the projected requirements for Operation and Maintenance Expenses for the Obligors and the Development for the ensuing calendar year (or, in the case of the initial Operating Budget, the remaining portion thereof) and provide the Independent Engineer and the Intercreditor Agent with a copy of such operating plan and budget (the “Operating Budget”).

 

  (b)

Each Operating Budget shall be prepared in accordance with a form provided to and accepted by the Independent Engineer prior to the Project Completion Date in its reasonable judgment (with any material changes to such form as may be confirmed to be reasonable by the Independent Engineer).

 

  (c)

Each Operating Budget shall set forth all material assumptions used in the preparation of such Operating Budget and each such Operating Budget shall become effective 30 days following delivery thereof to the Intercreditor Agent unless the Intercreditor Agent, acting reasonably and in consultation with the Independent Engineer, objects in writing (stating its reasons for such objection) to such Operating Budget prior to such 30th day; provided that the Intercreditor Agent shall have neither the right nor the obligation to approve or object to costs for Gas purchase contracts for the Development or any financing-related costs or expenses contained in the Operating Budget. If the Obligors do not have an effective annual Operating Budget before the beginning of any calendar year, until such proposed Operating Budget is effective, the Operating Budget most recently in effect shall continue to apply; provided that (A) any items of the proposed Operating Budget that have not been objected to shall be given effect in substitution of the corresponding items in the Operating Budget most recently in effect, (B) costs for Gas purchase contracts for the Development shall be as provided by the Obligors and (C) all other items shall be increased by the lesser of (x) 2.5% and (y) the increase proposed by the Obligors for such item in such proposed Operating Budget.

 

  (d)

The Obligors shall provide notice to the Independent Engineer and Intercreditor Agent of any material amendments to the Operating Budget that occur during the course of a calendar year. Any such amendment shall become effective 30 days following delivery thereof to the Intercreditor Agent unless the Intercreditor Agent, acting reasonably and in consultation with the Independent Engineer, objects to such amendment prior to such 30th day.

 

-69-

Calcasieu Pass - Common Terms Agreement


  10.6

Operating Statements and Reports

Within 60 days following the end of each fiscal quarter (other than the last fiscal quarter of any fiscal year) and 90 days following the end of each fiscal year, commencing with the close of the first full fiscal quarter after the earlier of (x) the Commercial Operation Date and (y) the date LPS1 Substantial Completion is achieved, the Borrower shall deliver to the Intercreditor Agent and the Independent Engineer quarterly and annual operating statements, respectively, which shall:

 

  (a)

correspond to the expenditure categories and monthly periods of the current annual Operating Budget and show all Cash Flows and all expenditures for Operation and Maintenance Expenses during such quarterly period and for the portion of the Borrower’s fiscal year then ended, and the fiscal year then ended, respectively;

 

  (b)

in the case of the quarterly operating statement, include:

 

  (i)

updated estimates of Operation and Maintenance Expenses for the balance of such fiscal year to which the operating statement relates;

 

  (ii)

a summary of key performance indicators used to monitor the operation of the Project Facilities during such quarterly period and capacity test results if any are performed during such quarterly period;

 

  (iii)

records on efficiency, performance and availability of the Project Facilities during such fiscal quarter;

 

  (iv)

discussion of any material deviation from the requirements set forth in Section 12.3 (Project Construction; Maintenance of Properties), stating in reasonable detail the necessary qualifications to such requirements;

 

  (v)

the cause, duration and projected loss of Cash Flows attributable to each material scheduled and unscheduled interruption in the liquefaction and other services to be provided under the LNG SPAs by the Project Facilities during such fiscal quarter and, with respect to any interruptions caused by a material defect or failure, the cause of and cost to repair such defect or failure; and

 

-70-

Calcasieu Pass - Common Terms Agreement


  (vi)

a summary of firm Gas supply arrangements into which the Borrower has entered and listing the pipelines with which firm transportation agreements have been executed and the volumes of capacity associated therewith;

 

  (c)

include a copy of any filing made by an Obligor:

 

  (i)

with FERC with respect to the Development; or

 

  (ii)

with the DOE with respect to the export of LNG from the Project Facilities,

(except in each case such filings as are routine or ministerial in nature), which copy may be provided by means of a link to the website where such filing is posted;

 

  (d)

include a copy of any filing made by any Person other than an Obligor:

 

  (i)

with FERC with respect to the Development in any proceeding in which a Obligor is the captioned party or respondent; or

 

  (ii)

with the DOE with respect to the export of LNG from the Project Facilities in any proceeding in which an Obligor is the captioned party or respondent,

(except in each case such filings as are routine or ministerial in nature), which copy may be provided by means of a link to the website where such filing is posted;

 

  (e)

be accompanied by a statement of sources and uses of funds for the periods covered by it and a discussion of the reason for any material:

 

  (i)

variance from the amount budgeted therefor in the relevant Operating Budget; and

 

  (ii)

variance in the actual costs for the then-current period from the costs incurred during the prior period; and

 

  (f)

be certified as materially complete and correct by an Authorized Officer of the Borrower.

 

  10.7

Insurance Reporting

 

  (a)

The Borrower shall provide to the Intercreditor Agent:

 

  (i)

evidence of Minimum Insurance set forth on, and subject to the provisions of, the Schedule of Minimum Insurance:

 

  (A)

by the later of (1) the Closing Date and (2) in respect of any Material Construction Contract, the date of issuance of the

 

-71-

Calcasieu Pass - Common Terms Agreement


 

“Notice to Proceed” or “FNTP” pursuant to such Material Construction Contract;

 

  (B)

prior to the transfer of care, custody and control in respect of each of LPS1, LPS2 and LPS3 in accordance with the Material Construction Contracts; and

 

  (C)

upon the renewal or replacement of any insurance policy required under the Schedule of Minimum Insurance;

 

  (ii)

notice as soon as reasonably practicable of:

 

  (A)

any failure to pay any premium on Minimum Insurance (and in any case, by the date falling ten days after it is due);

 

  (B)

any actual or reasonably anticipated material reduction in Minimum Insurance coverage (and in any case, within five Business Days after becoming aware of such reduction);

 

  (C)

any failure to maintain Minimum Insurance coverage (including any cancellation, termination or suspension (for any reason) of any Minimum Insurance) (and in any case, within five Business Days after becoming aware of such cancellation, termination or suspension);

 

  (D)

any single loss or event likely to give rise to a property damage or liability claim against an insurer for an amount in excess of $75 million (and in any case, within five Business Days after becoming aware of such loss or event);

 

  (E)

without prejudice to its other obligations under this Section 10.7 (Insurance Reporting), Article 5 (Insurance and Condemnation Proceeds and Performance Liquidated Damages) of the Common Security and Account Agreement or Section 12.28 (Insurance Covenant), any fact, event or circumstance that has caused, or that with the giving of notice or lapse of time would cause, it to be in breach of any provision of this Section 10.7 (Insurance Reporting), Article 5 (Insurance and Condemnation Proceeds and Performance Liquidated Damages) of the Common Security and Account Agreement or Section 12.28 (Insurance Covenant) or the requirements of any of the Borrower’s Minimum Insurance policies, and:

 

  (1)

the steps it proposes to take in order to remedy such breach or, if such breach cannot be remedied, to mitigate the risk or liability to which the Project

 

-72-

Calcasieu Pass - Common Terms Agreement


 

Facilities have been or shall reasonably be expected to be exposed by virtue of the occurrence of such breach; and

 

  (2)

its good faith estimate of the period required to implement, and the cost of, such steps.

 

  (b)

The evidence of Minimum Insurance provided pursuant to Section 10.7(a)(i)(A) (Insurance Reporting) above shall be provided in the form of certificates of insurance, binders or other customary documentation evidencing the existence of all insurance required to be maintained at such time by the Obligors, together with a certificate of the Borrower setting forth the insurance obtained and stating:

 

  (i)

that such insurance required to be maintained at such time by the Obligors as set forth in the Schedule of Minimum Insurance has been obtained and in each case is in full force and effect;

 

  (ii)

that such insurance complies with the requirements of the Schedule of Minimum Insurance and is otherwise in accordance with the Finance Documents in all material respects; and

 

  (iii)

that all premiums then due and payable on all such insurance have been paid.

 

  10.8

Copies of Finance Documents

Promptly following the Closing and following entry by any Obligor into a new Finance Document, the Borrower shall deliver copies of such newly executed Finance Document to the Collateral Agent, Intercreditor Agent, each Facility Agent and each Facility Lender party to the Finance Documents.

 

  10.9

Construction Budget and Schedule

If the Construction Budget and Schedule is amended, supplemented or otherwise modified in accordance with the Finance Documents, the Borrower shall (a) to the extent such update was made in reliance on the proviso in Section 9.1(a)(i) (Change Orders), deliver to the Intercreditor Agent such updated Construction Budget and Schedule in connection with delivery of financial statements pursuant to Section 10.1(a) (Accounting, Financial and Other Information) and (b) to the extent such update was not made in reliance on the proviso in Section 9.1(a)(i) (Change Orders), promptly deliver to the Intercreditor Agent such updated Construction Budget and Schedule in connection with any requests for Change Orders pursuant to Section 9.1 (Change Orders) requiring the consent of the Intercreditor Agent, acting in reliance on and in consultation with the Independent Engineer.

 

-73-

Calcasieu Pass - Common Terms Agreement


11.

RESTRICTED PAYMENTS

 

  11.1

Conditions to Restricted Payments

Restricted Payments may be made provided that each of the following, and no other, conditions has been satisfied:

 

  (a)

no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing or could reasonably be expected to occur as a result of such Restricted Payment;

 

  (b)

(i) the Historical DSCR for the most recent 12-month period (calculated for this purpose based on the rolling four-quarter average unless the Project Completion Date has occurred less than four full quarters prior and excluding any amount contributed during such measurement period under the cure right in Section 12.25 (Historical DSCR)) and (ii) the Fixed Projected DSCR for the 12-month period beginning on the Quarterly Payment Date on or immediately prior to the proposed date of the Restricted Payment are, in each case, at least 1.25:1;

 

  (c)

the Senior Facilities Debt Service Reserve Account is funded (with cash or Acceptable Debt Service Reserve LCs) with the then-applicable Senior Facilities Reserve Amount;

 

  (d)

the Project Completion Date has occurred;

 

  (e)

no outstanding LC Loans or LC Reimbursement Payments are outstanding as of the date of such Restricted Payment;

 

  (f)

the then-Required LNG SPAs are in full force and effect and no actual LNG SPA Prepayment Event or Unmatured LNG SPA Prepayment Event has occurred and is continuing in respect of which the prepayment and cancellation required by the occurrence of such event in accordance with Section 8.2 (LNG SPA Mandatory Prepayment) has not been made in full;

 

  (g)

no other Restricted Payment (other than any Restricted Payment permitted under Section 11.2 (Certain Restricted Payments)) has been made during the calendar quarter of the proposed Restricted Payment; and

 

  (h)

at least two Business Days prior to the proposed date of such Restricted Payment, the Intercreditor Agent has received a certificate from the Borrower confirming that each of the conditions set forth in in this Section 11.1 (Conditions to Restricted Payments) have been satisfied and setting forth the calculation of the Historical DSCR and the Fixed Projected DSCR in clause (b) above.

 

-74-

Calcasieu Pass - Common Terms Agreement


  11.2

Certain Restricted Payments

The following payments may be made at any time in accordance with the terms of this Agreement and the other Finance Documents, without complying with the conditions set forth in Section 11.1 (Conditions to Restricted Payments):

 

  (a)

reimbursements of equity pursuant to Section 3.4(a)(ii) (Mandatory Prepayments – Performance Liquidated Damages);

 

  (b)

reimbursements of equity pursuant to Section 5.2(h) (Insurance and Condemnation Proceeds) of the Common Security and Account Agreement;

 

  (c)

reimbursements of Drawstop Equity Contributions in accordance with Section 4.5(c)(iii) (Deposits and Withdrawals – Construction Account) of the Common Security and Account Agreement, but subject to all conditions precedent set forth in Section 4.2 (Conditions to Each Advance) for an Advance in connection with such reimbursement of the Drawstop Equity Contributions have been met or waived and solely to the extent the proceeds of such Drawstop Equity Contributions have been used to pay Project Costs; and

 

  (d)

so long as the Obligors have satisfied the conditions to the Project Completion Date in Section 14.1 (Conditions to Occurrence of the Project Completion Date), the making of the Project Completion Date Distribution, if any, in accordance with Section 4.5(c)(iv) (Deposits and Withdrawals – Construction Account) of the Common Security and Account Agreement and Section 14.2(c) (Project Completion Date Waterfall) hereof.

 

12.

OBLIGOR COVENANTS

Each Obligor shall comply at all times with the following covenants:

 

  12.1

Use of Proceeds

The Obligors shall use the proceeds of (a) the Initial Senior Debt as specified in the Credit Facility Agreement and (b) any other Senior Debt in accordance with the Facility Agreement applicable thereto.

 

  12.2

Maintenance of Existence, Franchises, Etc.

 

  (a)

Each Obligor shall maintain its legal existence as a limited liability company;

 

-75-

Calcasieu Pass - Common Terms Agreement


  (b)

no Obligor shall take any action to amend or modify its Constitutional Documents in a manner that is in any material respect adverse to the interests of the Facility Lenders or such Obligor’s ability to comply with the Finance Documents; and

 

  (c)

 

  (i)

each of Obligors shall promptly provide copies of any amendments to its Constitutional Documents to the Intercreditor Agent;

 

  (ii)

each Obligor shall maintain and renew all of the powers, licenses, rights, privileges and franchises necessary for the Development and in the normal conduct of its business as conducted or proposed to be conducted, except where the failure to do so could not reasonably be expected to have a Material Adverse Effect;

 

  (iii)

no Obligor shall change, alter or modify its legal business name, jurisdiction of organization or type of organization, in each case without providing the Intercreditor Agent with at least 30 days’ prior notice and without having satisfied its obligations under Section 12.31 (Preservation of Collateral; Further Assurances); and

 

  (iv)

no Obligor shall cease to be an entity disregarded for US federal, state and local income tax purposes.

 

  12.3

Project Construction; Maintenance of Properties

 

  (a)

The Obligors shall construct and complete, operate and maintain the Project Facilities, and cause the Project Facilities to be constructed, operated and maintained, as applicable:

 

  (i)

consistent in all material respects with Prudent Industry Practice, the Material Construction Contracts, the Construction Budget and Schedule, the Operating Manual, applicable Government Rules, and the other Transaction Documents, and in accordance with the requirements for maintaining the effectiveness of the material warranties of the Construction Contractors; and

 

  (ii)

following the Project Completion Date, within the then-effective Operating Budget; provided that:

 

  (A)

the Obligors may exceed in the aggregate for all operating budget categories in any Operating Budget by 20% or less per line item of the amount therefor and 10% or less of the aggregate budgeted amount therefor, in each case on an annual basis, but excluding, for purposes of calculating the foregoing allowable increases, amounts in the then- effective Operating Budget for Gas purchases; and

 

-76-

Calcasieu Pass - Common Terms Agreement


  (B)

the Obligors may exceed the Operating Budget and any category thereof:

 

  (1)

with respect to payments under Gas purchase contracts for the Development;

 

  (2)

as required by law or regulation, Industry Standards, Prudent Industry Practice or for compliance with any Permit applicable to the Obligors or the Development (or to cure or remove the effect of any termination, suspension, or impairment of any Permit), as certified by the Borrower (with the reasonable concurrence of the Independent Engineer); or

 

  (3)

to the extent required to respond to an emergency or accident, the failure to respond to which could reasonably be expected to create a risk of personal injury or significant physical damage to the Project Facilities or material threat to the environment, in which case:

 

  (I)

if the Obligors reasonably determine that there is sufficient time to do so prior to responding to any such emergency or accident, the Borrower shall substantiate the expenses expected to be incurred by the Obligors in connection with such emergency or accident to the reasonable satisfaction of the Intercreditor Agent; or

 

  (II)

if the Obligors reasonably determine that there is not sufficient time to take the actions described in sub-clause (3) above prior to responding to any such emergency or accident, promptly following such emergency or accident, the Borrower shall describe in writing to the Intercreditor Agent the steps that were taken by the Obligors in respect of such emergency or accident and the expenses incurred by the Obligors in connection therewith, all in reasonable detail.

 

-77-

Calcasieu Pass - Common Terms Agreement


  12.4

Books and Records; Inspection Rights

 

  (a)

The Obligors shall make available to the Intercreditor Agent, on request, copies or extracts of books and records of the Obligors:

 

  (i)

when a Loan Facility Event of Default has occurred and is Continuing; and

 

  (ii)

otherwise up to two times (which shall be reasonably spaced within the applicable period) per calendar year during normal business hours upon 30 days’ advance notice,

subject to the confidentiality arrangements pursuant to Section 12.6 (Confidentiality) of the Common Security and Account Agreement and Section 23.7 (Confidentiality) below.

 

  (b)

The Obligors shall not, without the prior consent of the Intercreditor Agent (not to be unreasonably withheld, conditioned or delayed), change the end date of their fiscal years.

 

  (c)

The Obligors shall keep proper books and records in accordance with GAAP in all material respects.

 

  12.5

Material Project Agreements

 

  (a)

Each Obligor shall maintain in effect all Material Project Agreements (other than Real Property Documents) that have been entered into and to which it is a party except:

 

  (i)

to the extent a Material Project Agreement is permitted to expire, be terminated or replaced under the Finance Documents or expires or is replaced in accordance with its terms; and

 

  (ii)

to the extent provided under Section 8.1 (LNG SPA Maintenance) and Section 8.2 (LNG SPA Mandatory Prepayment) in relation to LNG SPAs.

 

  (b)

Each Obligor shall comply with its material contractual obligations, and, subject to Section 12.5(e) (Material Project Agreements) below, enforce against Material Project Counterparties its material rights and their material covenants and obligations, under the Material Project Agreements (other than Real Property Documents) then in effect to which it is a party.

 

  (c)

No Obligor shall agree to any amendment or modification of, or waiver relating to, any Material Project Agreement (other than Real Property Documents) to which it is a party that could reasonably be expected to have a Material Adverse Effect or would materially breach the terms of

 

-78-

Calcasieu Pass - Common Terms Agreement


 

the Finance Documents; provided that amendments or modifications to LNG SPAs as permitted under Section 8.3 (Amendment of LNG SPAs) shall in any case be permitted; provided further that Change Orders as permitted under Section 9.1 (Change Orders) shall in any case be permitted.

 

  (d)

Other than with respect to Real Property Documents, no Obligor shall:

 

  (i)

assign or transfer any interest under any Material Project Agreement without the prior written consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties (except for assignments and transfers contemplated in connection with the Common Security and Account Agreement and other Security Documents);

 

  (ii)

consent to any counterparty assigning or transferring any interest under any Material Project Agreement, if such Obligor has consent rights under such Material Project Agreement, without the prior written consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties; except

 

  (A)

if such assignment or transfer could not reasonably be expected to have a Material Adverse Effect; or

 

  (B)

for assignments and transfers permitted or contemplated in the Common Security and Account Agreement, Direct Agreements or other Security Documents; or

 

  (iii)

permit any Material Project Counterparty to substitute, diminish or otherwise replace any performance security, letter of credit or guarantee supporting such Material Project Counterparty’s obligations thereunder (including, for the avoidance of doubt, any replacement of the guaranties described in clause (a) or clause (b) of the definition of “Parent Guarantees”), except to the extent that such Material Project Counterparty is permitted to do so without the consent of the Borrower or Guarantor, as applicable, under the terms of such Material Project Agreement.

 

  (e)

No Obligor shall initiate or settle arbitration or disputes if the amount in controversy in such arbitration, dispute or settlement is in excess of (x) $15 million in the case of a Real Property Document and (y) $15 million in the case of any other Material Project Agreement.

 

  (f)

The applicable Obligor promptly shall provide the Intercreditor Agent with copies (or ensure that copies are provided) of any material amendments to, or material waivers relating to, the Material Project Agreements that are permitted under the Finance Documents or that have

 

-79-

Calcasieu Pass - Common Terms Agreement


 

otherwise been entered into with the consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties.

 

  (g)

The Obligors shall not enter into any new Material Project Agreement or any Subsequent Material Project Agreements (other than Real Property Documents) without the prior written consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties; provided that:

 

  (i)

the Obligors may enter into a Replacement Material Contract without the prior written consent of the Intercreditor Agent or any Facility Lender, if:

 

  (A)

in the case of a termination of any Material Project Agreement (other than an LNG SPA), the Obligors (A) shall have entered into a Replacement Material Contract within 60 days (as such period may be extended an additional 30 days provided the Obligors are proceeding with diligence to replace such terminated Material Project Agreement) after such termination and (B) shall have caused such Replacement Material Contract to become subject to the Liens granted under the Security Documents; or

 

  (B)

in the case of any termination of an LNG SPA, the Borrower (A) shall have entered into a Replacement Material Contract within 90 days (as such period may be extended an additional 90 days provided the Obligors are proceeding with diligence to replace such terminated Material Project Agreement) after the date of such termination and (B) shall have caused such Replacement Material Contract to become subject to the Liens granted under the Security Documents to the same extent as the LNG SPA that was terminated, and in each case, the termination of such LNG SPA could not reasonably be expected to result in a Material Adverse Effect;

 

  (ii)

except for gas supply contracts that constitute Material Project Agreements, the Obligors may enter into new gas supply contracts (copies of which shall be delivered to the Intercreditor Agent) without the prior written consent of the Intercreditor Agent in accordance with Section 12.27(a) (Gas Transportation Arrangements; Gas Purchase Arrangements); and

 

  (iii)

the Borrower may enter into new LNG SPAs in accordance with Section 12.5(k) (Material Project Agreements).

 

-80-

Calcasieu Pass - Common Terms Agreement


  (h)

In connection with any new Material Project Agreement and any Subsequent Material Project Agreement (other than Real Property Documents), the applicable Obligor shall deliver to the Intercreditor Agent, within 30 days following execution of such new Material Project Agreement or any Subsequent Material Project Agreement (with a form of such document to be delivered prior to execution of such new Material Project Agreement or any Subsequent Material Project Agreement):

 

  (i)

each Security Document, if any, necessary to grant the Collateral Agent a first priority perfected Lien in such Subsequent Material Project Agreement (subject only to Permitted Liens);

 

  (ii)

evidence of the authorization of the applicable Obligor to execute, deliver and perform such Subsequent Material Project Agreement;

 

  (iii)

a certificate of the Borrower certifying that all Permits necessary for the execution, delivery and performance of such Subsequent Material Project Agreement have been duly obtained, were validly issued and are in full force and effect;

 

  (iv)

an opinion of counsel to the applicable Obligor and, if a Direct Agreement is required to be obtained from such counterparty pursuant to Section 3.4 (Direct Agreements) of the Common Security and Account Agreement, applying the effort standard set forth in Section 3.4 (Direct Agreements) of the Common Security and Account Agreement to obtaining such opinion as is applicable to obtaining the related Direct Agreement, an opinion of counsel to the counterparty to such new Material Project Agreement or such Subsequent Material Project Agreement; and

 

  (v)

a Direct Agreement in respect of such Subsequent Material Project Agreement, but only to the extent such Direct Agreement is required pursuant to Section 3.4 (Direct Agreements) of the Common Security and Account Agreement for an equivalent Material Project Agreement.

 

  (i)

Each Obligor shall maintain, preserve and protect, or make contractual or other provisions to cause to be maintained, preserved and protected, all of the real property interests evidenced by the Real Property Documents except (x) to the extent such Real Property Document is permitted to expire, be terminated or replaced under the Finance Documents or expires or terminates pursuant to its terms and is replaced with substantially equivalent real property interests to the extent necessary for the Development at such time or (y) where failure to do so could not reasonably be expected to have a Material Adverse Effect.

 

-81-

Calcasieu Pass - Common Terms Agreement


  (j)

The prior written consent of the Intercreditor Agent (acting on the instruction of the Requisite Intercreditor Parties) shall be required in connection with the execution by an Obligor of a document evidencing a real property interest if:

 

  (i)

such real property interest replaces (or is substituted for) a real property interest in a then-existing Real Property Document and such replaced real property interest is necessary at such time for the Development; or

 

  (ii)

if such real property interest does not replace (or is not substituted for) a real property interest in a then-existing Real Property Document, such real property interest:

 

  (A)

is, at such time, necessary for the Development;

 

  (B)

is required to be included in a mortgage pursuant to requirements of Section 3.2(f)(ii) (Security Interests to be Granted by the Obligors – Real Property) of the Common Security and Account Agreement; and

 

  (C)

is evidenced by a Real Property Document which by its terms imposes upon a Obligor obligations or liabilities with an aggregate value in excess of $50 million over its term and is for a term of greater than seven (7) years;

 

 

provided, in the case of each of clauses (i) and (ii) above, that no such consent shall be required if the applicable real property interest is being acquired in order to comply with (x) the requirements of any Permit or applicable Government Rules, (y) obligations of any Obligor pursuant to a Material Project Agreement or (z) Prudent Industry Practice pertaining to safety or security measures.

 

  (k)

The Borrower shall not enter into any LNG SPA except as permitted by Section 8.1(a) (LNG SPA Maintenance), Section 8.4 (Sale of Supplemental Quantity), Section 8.5 (Sale of Pre-Commercial Quantities) and Section 12.5(g)(i)(B) (Material Project Agreements).

 

  12.6

Compliance with Law

 

  (a)

The Obligors shall comply in all material respects with all material applicable Government Rules (excluding tax laws as to which Section 12.13 (Taxes) is applicable and Environmental Laws as to which Section 12.7 (Environmental Compliance) is applicable).

 

-82-

Calcasieu Pass - Common Terms Agreement


  (b)

No Obligor shall Knowingly engage in any activity that violates any Anti-Terrorism and Money Laundering Law or OFAC Law to the extent applicable to such entity.

 

  (c)

The Obligors will not, and will require that their respective Affiliates, directors and officers shall not, directly or, to the Obligors’ Knowledge, indirectly, use the proceeds of the Loans, or lend, contribute or otherwise make available such proceeds to any Subsidiary, joint venture partner or other Person:

 

  (i)

in furtherance of an offer, payment, promise to pay or authorization of the payment or giving of money or anything else of value, to any Person in violation of any Anti-Terrorism and Money Laundering Laws, Applicable Anti-Corruption Laws or Sanctions;

 

  (ii)

to fund any activities or business of or with any Sanctioned Person, or in any country, territory, or region, that, at the time of such funding, is, or whose government is, the target of Sanctions administered OFAC or by the US Department of State, the European Union or Her Majesty’s Treasury, including, without limitation, currently the Crimea region, Cuba, Iran, North Korea, and Syria; or

 

  (iii)

in any other manner that would result in a violation of any Anti- Terrorism and Money Laundering Laws, Applicable Anti- Corruption Laws or Sanctions administered by the United States, including by OFAC or by the US Department of State, the European Union, any EU Member State or Her Majesty’s Treasury of the United Kingdom, by any Person (including any Person participating in the Loans, whether as Facility Lender, Intercreditor Agent, or otherwise).

 

  (d)

The Borrower agrees that if it becomes aware of or receives any notice that a Obligor, any Affiliate or any Person holding a legal or beneficial interest therein (whether directly or indirectly) is a Sanctioned Person (a “Sanctions Violation”), the Borrower shall promptly:

 

  (i)

give notice to the Intercreditor Agent of such Sanctions Violation; and

 

  (ii)

comply with all applicable laws governing such Sanctions with respect to such Sanctions Violation (regardless of whether the Sanctioned Person is located within the jurisdiction of the United States).

 

-83-

Calcasieu Pass - Common Terms Agreement


  (e)

The Borrower authorizes and consents to the Intercreditor Agent and each Senior Creditor Group Representative taking any and all steps such parties deem necessary to comply with all applicable laws governing such Sanctions with respect to any such Sanctions Violation, including the “freezing” or “blocking” of assets and reporting such action to the applicable regulatory authorities.

 

  12.7

Environmental Compliance

The Obligors shall:

 

  (a)

comply in all material respects with applicable Environmental Laws;

 

  (b)

provide to the Intercreditor Agent (with a copy to each Facility Agent) (i) as promptly as practicable following the Closing Date, the initial version(s) of an “Environmental and Social Management Plan” and (if applicable) “Equator Principles Action Plan” with respect to the Borrower’s material compliance with Equator Principles, in each case, developed with the reasonable cooperation of the Independent Engineer, and thereafter (but no more frequently than semi-annually), any updates thereto, and (ii) on an annual basis for each fiscal year following the Closing Date, a certification that the Borrower is in compliance in all material respects with any requirements of the Equator Principles (including reporting requirements with respect to greenhouse gas emissions) to the extent applicable to the Borrower; and

 

  (c)

not Release, and use commercially reasonable efforts not to permit the Release by its Construction Contractors or agents of, any Hazardous Materials at, on, under or from the Project Facilities or any Real Estate on which any Project Facilities are situated in quantities or concentrations that could reasonably be expected to result in a Material Adverse Effect.

 

  12.8

Permits

 

  (a)

The Obligors shall obtain by the time they are required, maintain in full force and effect, and comply in all material respects with all applicable material Permits set forth on Schedule F (Material Permits) (excluding Export Authorizations, as to which Section 12.9 (Export Authorizations) is applicable, and the FERC Order, as to which Section 12.10 (FERC Order) is applicable).

 

  (b)

The Obligors shall not amend or modify a material Permit set forth on Schedule F (Material Permits) or any conditions thereof (excluding Export Authorizations, as to which Section 12.9 (Export Authorizations) is applicable, and the FERC Order, as to which Section 12.10 (FERC Order) is applicable); provided that the Obligors may amend or modify such Permits and any conditions thereof so long as such amendment or

 

-84-

Calcasieu Pass - Common Terms Agreement


 

modification could not reasonably be expected to have a Material Adverse Effect or result in an Impairment of such Permit and such amendment or modification is not materially more restrictive or onerous on the applicable Obligor.

 

  12.9

Export Authorizations

 

  (a)

The Obligors shall use all reasonable efforts to maintain in full force and effect and will comply in all material respects with both the FTA Authorization and the Non-FTA Authorization.

 

  (b)

If an Export Authorization is Impaired, the Obligors shall use all reasonable efforts to promptly and diligently take reasonable steps to reverse such Impairment.

 

  12.10

FERC Order

 

  (a)

From and after the Closing Date, the Obligors shall maintain in full force and effect and comply in all material respects with the FERC Order.

 

  (b)

The Obligors shall not propose to amend or modify the FERC Order or any conditions of the FERC Order; provided that the Obligors may amend or modify the FERC Order and any conditions thereof so long as such amendment or modification could not reasonably be expected to have a Material Adverse Effect and such amendment or modification is not materially more restrictive or onerous on the applicable Obligor.

 

  12.11

Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages

The Intercreditor Agent, each Senior Creditor Group Representative and the Independent Engineer shall have the right to witness and verify each Performance Test and the Lenders’ Reliability Test, and no Obligor shall:

 

  (a)

permit a Performance Test or Lenders’ Reliability Test to be performed without giving the Intercreditor Agent at least five Business Days’ prior notice thereof (or such shorter period agreed by the Independent Engineer); or

 

  (b)

agree in a dispute with the any Construction Contractor with respect to the amount of any Performance Liquidated Damages or Delay Liquidated Damages, or to a settlement with respect to such damages, in excess of $15 million without prior approval of the Intercreditor Agent, acting reasonably and in consultation with the Independent Engineer.

 

-85-

Calcasieu Pass - Common Terms Agreement


  12.12

Inspection Rights

The Obligors shall grant access to the Site to the Consultants and designated representatives of Facility Lenders at the times and in the manner described in Section 13.3 (Access).

 

  12.13

Taxes

Each Obligor (or, for the purposes of this Section 12.13 (Taxes) as it relates to US federal income taxes, if it is a disregarded entity for US federal income tax purposes, its owner for US federal income tax purposes) shall pay or cause to be paid all material Taxes (if any) imposed on it or its property by any Governmental Authority, when due, giving effect to any applicable extensions, unless these are being contested in good faith and by appropriate proceedings and an appropriate reserve has been established in respect thereof in accordance with GAAP. Each Obligor shall notify the Intercreditor Agent of any material dispute with the relevant tax authorities. Each Obligor (or, for the purposes of this Section 12.13 (Taxes) as it relates to US federal income taxes, if it is a disregarded entity for US federal income tax purposes, its owner for US federal income tax purposes) will promptly pay or cause to be paid any valid, final judgment rendered upon the conclusion of the relevant proceeding, if any, enforcing such Tax and cause it to be satisfied of record.

 

  12.14

Limitation on Indebtedness

The Obligors shall not incur Indebtedness other than the following (with any baskets measured in the aggregate among all the Obligors):

 

  (a)

Senior Debt, including any reborrowing of any Working Capital Debt in accordance with its terms;

 

  (b)

Permitted Replacement Debt or other Indebtedness expressly contemplated by a Material Project Agreement (including guarantees permitted by Section 12.15 (Guarantees));

 

  (c)

Permitted Additional Working Capital Debt;

 

  (d)

Subordinated Debt in an amount not to exceed $250 million in the aggregate;

 

  (e)

intercompany Indebtedness between or among the Obligors, all of which shall be Subordinated Debt;

 

  (f)

Indebtedness incurred under Permitted Hedging Instruments not covered under clause (a) above;

 

-86-

Calcasieu Pass - Common Terms Agreement


  (g)

Indebtedness in respect of any bankers’ acceptances, letters of credit, warehouse receipts or similar facilities, in each case, incurred in the ordinary course of business;

 

  (h)

purchase money Indebtedness and capital leases or guarantees of the same, in a principal amount not exceeding $50 million in the aggregate to finance the purchase or lease of assets for the Development other than those financed with the proceeds of Senior Debt; provided that if such obligations are secured, they are secured only by Liens upon the assets being financed or the proceeds of such assets;

 

  (i)

any other unsecured Indebtedness incurred after the Project Completion Date in an aggregate amount outstanding at any one time not to exceed $100 million for general corporate purposes (including, for the avoidance of doubt, to reduce the principal amount relating to any revolving loans under a Senior Debt Instrument to $0 as and when required under the terms of such Senior Debt Instrument);

 

  (j)

to the extent constituting Indebtedness, indebtedness arising from honoring by a bank or other financial institution of a check, draft or similar instrument drawn against insufficient funds in the ordinary course or other cash management services in the ordinary course of business;

 

  (k)

Indebtedness in respect of netting services, overdraft protections and otherwise in connection with deposit accounts;

 

  (l)

contingent liabilities incurred in the ordinary course of business, including the acquisition or sale of goods, services, supplies or merchandise in the normal course of business, the endorsement of negotiable instruments received in the normal course of business and indemnities provided under any of the Transaction Documents;

 

  (m)

to the extent constituting Indebtedness, obligations in respect of performance bonds, bid bonds, appeal bonds, surety bonds, indemnification obligations, obligations to pay insurance premiums, take- or-pay obligations contained in supply agreements and similar obligations incurred in the ordinary course of business;

 

  (n)

trade debt, trade accounts, purchase money obligations or other similar Indebtedness incurred in the ordinary course of business, which:

 

  (i)

is not more than 90 days past due; or

 

  (ii)

is being contested in good faith and by appropriate proceedings;

 

-87-

Calcasieu Pass - Common Terms Agreement


  (o)

Indebtedness consisting of the financing of insurance premiums in customary amounts consistent with the operations and business of the Obligors in the ordinary course of business; and

 

  (p)

other Indebtedness incurred with the consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties, together with any refinancing thereof.

 

  12.15

Guarantees

No Obligor shall guarantee the obligations of others (other than the other Obligor) except for guarantees expressly contemplated by a Finance Document, a Material Project Agreement or a material Permit.

 

  12.16

Limitation on Liens

The Obligors shall not assume, incur, permit or suffer to exist any Lien on any of its assets, whether now owned or hereafter acquired, except for Permitted Liens.

 

  12.17

Sale of Project Property

No Obligor shall sell, lease or otherwise dispose of Project Property, in one transaction or a series of transactions, in excess of $50 million per year without the consent of the Intercreditor Agent and no Obligor shall sell, lease or otherwise dispose of the TransCameron Pipeline, except in each case that no consent of the Intercreditor Agent shall be required for:

 

  (a)

[Reserved];

 

  (b)

dispositions in compliance with any applicable court or governmental order;

 

  (c)

dispositions of obsolete, superfluous or replaced assets, or assets that are not, or cease to be, necessary for the construction and operation of the Project Facilities substantially in the manner contemplated in this Agreement;

 

  (d)

sales or other dispositions of LNG in accordance with any LNG SPAs as permitted under the Finance Documents;

 

  (e)

sales of Gas in the ordinary course of business;

 

  (f)

sales, transfers or other dispositions of Authorized Investments;

 

  (g)

Restricted Payments made in accordance with the Finance Documents;

 

  (h)

liquefaction and other services in the ordinary course of business;

 

-88-

Calcasieu Pass - Common Terms Agreement


  (i)

settlement, release, waiver or surrender of contract, tort or other claims in the ordinary course of business or a grant of a Lien not prohibited by the Finance Documents;

 

  (j)

the transfer or novation of Permitted Hedging Instruments in accordance with the Finance Documents;

 

  (k)

conveyance of gas interconnection or metering facilities to gas transmission companies and conveyance of electricity substations to electricity providers pursuant to its electricity purchase arrangements for operating the Project Facilities; and

 

  (l)

dispositions of other Project Property if an Obligor replaces such Project Property within 180 days following such disposition or has obtained a commitment to replace such Project Property within 180 days following such disposition and replaces such Project Property within 270 days following such disposition.

Proceeds of any such disposition by the Borrower pursuant to this Section 12.17 (Sale of Project Property) shall be deposited in the Pre-Completion Revenues Account or the Revenue Account; provided that proceeds of any disposition of assets requiring mandatory prepayment under Section 3.4 (Mandatory Prepayments) shall be deposited into the Additional Proceeds Prepayment Account.

 

  12.18

Merger, Division, Liquidation and Sale of All Assets

No Obligor shall liquidate itself, enter into any merger or division or sell or otherwise transfer all or substantially all its assets to any Person or any series of any Obligor (including by operation of law), except to any series of Obligor who agrees in writing to become an Obligor hereunder.

 

  12.19

Limitation on Investments and Loans

No Obligor shall make any investments, loans or advances to any Person other than:

 

  (a)

Authorized Investments;

 

  (b)

by way of trade credit in the ordinary course of business;

 

  (c)

as specifically contemplated under the Finance Documents;

 

  (d)

as expressly contemplated by the terms of the Material Project Agreements then in effect to which it is a party;

 

  (e)

surety and performance bonds and workers’ compensation, utility, lease, tax, performance and similar deposits, advance payments in the ordinary

 

-89-

Calcasieu Pass - Common Terms Agreement


 

course of business on usual commercial terms and prepaid expenses in the ordinary course of business, including cash deposits incurred in connection with natural gas purchases;

 

  (f)

[Reserved];

 

  (g)

investments pursuant to Permitted Hedging Instruments;

 

  (h)

[Reserved];

 

  (i)

[Reserved];

 

  (j)

investments, loans or advances among and between the Obligors; provided that amounts owing thereunder are Subordinated Debt; and

 

  (k)

loans from either the Borrower or the Guarantor to Pledgor, the Sponsor or their respective Affiliates (other than Guarantor or Borrower), but only to the extent that such loans are made with cash available to the Borrower to make a Restricted Payment and after meeting the test to make Restricted Payments under Section 11.1 (Conditions to Restricted Payments).

 

  12.20

Nature of Business

 

  (a)

The Obligors shall not (i) change the limited nature of their business in any material respect from that contemplated by the Common Terms Agreement and the Common Security and Account Agreement in the form existing on the Closing Date or (ii) engage in retail sales of natural gas in such a manner and to such an extent so as to cause either Obligor to become subject to regulation as a “gas utility” under the Louisiana Government Rules. In the event either Obligor engages in retail sales of natural gas in a manner that would cause it to become a “holding company” or a “subsidiary company” of a “holding company” (each as defined under PUHCA), it shall (A) comply in all material respects with all applicable provisions of PUHCA and (B) use commercially reasonable efforts to obtain an exemption from regulation under PUHCA.

 

  (b)

The Borrower shall not permit to exist any Subsidiary of the Borrower.

 

  (c)

The Guarantor shall not permit to exist any Subsidiary of the Guarantor.

 

  12.21

Transactions with Affiliates

No Obligor shall directly or indirectly enter into any transaction or agreement with or for the benefit of an Affiliate (including guarantees and assumptions of obligations of an Affiliate) in relation to the Development, except:

 

  (a)

agreements that are Material Project Agreements or required or contemplated by any Material Project Agreement;

 

-90-

Calcasieu Pass - Common Terms Agreement


  (b)

any other agreement relating to the Development entered into prior to the Closing Date that is disclosed on Schedule J (Transactions With Affiliates) hereto;

 

  (c)

to the extent required by applicable law or regulation; or

 

  (d)

transactions or agreements entered into on fair and commercially reasonable terms (from the perspective of the relevant Obligor) that (i) could not reasonably be expected to cause a Material Adverse Effect and (ii) are not materially less favorable in the aggregate to such Obligor than such Obligor would obtain in a comparable agreement with independent parties acting at arm’s length (or, if there is no comparable arm’s-length transaction, then on terms reasonably determined by the board of managers of the Borrower to be fair and reasonable);

provided that:

 

  (i)

this covenant shall not apply to (A) transactions between or among the Obligors, (B) any issuance of equity interests of any Obligor to its direct parent and (C) Permitted Payments; and

 

  (ii)

any such agreement that constitutes a Subsequent Material Project Agreement shall be subject to the terms of Section 12.5 (Material Project Agreements).

 

  12.22

Hedging Arrangements

 

  (a)

No Obligor shall enter into Hedging Instruments other than Permitted Hedging Instruments.

 

  (b)

The Borrower shall enter into and thereafter maintain in full force and effect, from time to time, one or more interest rate Permitted Hedging Instruments:

 

  (i)

no later than 45 days following the Closing Date, with respect to no less than 50%, but no more than 105% (calculated on a weighted average basis) of the projected aggregate outstanding balance of the Senior Debt projected to be outstanding (as determined by the Borrower in accordance with the Base Case Forecast) until the latest payment date occurring at the expiration of the 20-year notional amortization period; and

 

  (ii)

no later than 45 days following the Closing Date, with respect to no less than 75%, but no more than 105% (calculated on a weighted average basis) of the projected aggregate outstanding balance of the Senior Debt projected to be outstanding (as determined by the Borrower in accordance with the Base Case Forecast) until the Maturity Date;

 

-91-

Calcasieu Pass - Common Terms Agreement


provided that for purposes of calculating such percentage in the foregoing sub-clauses (i) and (ii) above, (w) the principal balance of the Working Capital Facility and/or Working Capital Debt shall be excluded, (x) any obligations incurred under the Permitted Senior Debt Hedging Instruments shall be excluded, and (y) any such Senior Debt which bears a fixed interest rate shall be deemed subject to a Permitted Hedging Instrument.

 

  (c)

If, due to a mandatory prepayment made in accordance with Section 3.4 (Mandatory Prepayments), a voluntary prepayment made in accordance with Section 3.5 (Voluntary Prepayments) or otherwise, the aggregate notional amount of the Permitted Hedging Instruments (which, for the avoidance of doubt, shall only include Permitted Hedging Instruments that are Interest Rate Hedging Instruments) on any Quarterly Payment Date is greater than 105% (or, if 105% hedging is not permitted by applicable law, 100%) (in each case, calculated on a weighted average basis) of the projected aggregate outstanding balance of the Senior Debt, within 45 days, the Borrower shall reduce the amount that is hedged under the Permitted Hedging Instruments (in the proportion allocated to each Permitted Hedging Instrument as may be determined by the Borrower as long as the Borrower has allocated the reduction pro rata among each Permitted Hedging Instrument, after taking into account any back-to-back or offsetting arrangements related thereto) such that the aggregate notional amount of the Permitted Hedging Instruments is not more than 105% (or, if 105% hedging is not permitted by applicable law, 100%) (in each case, calculated on a weighted average basis) of the projected aggregate outstanding balance of the Senior Debt on such Quarterly Payment Date (any such amount of the Permitted Hedging Instruments that is required to be so reduced, a “Hedging Excess Amount”).

 

  12.23

Accounts

 

  (a)

No Obligor shall maintain any accounts in contravention of Article 4 (Cash Flow and Accounts) of the Common Security and Account Agreement.

 

  (b)

(i) All revenues of the Obligors shall be deposited in accordance with the Common Security and Account Agreement and (ii) the Obligors shall direct third parties to deposit all amounts required to be paid to the Obligors in accordance with the Common Security and Account Agreement.

 

  12.24

Separateness

Each Obligor shall at all times:

 

-92-

Calcasieu Pass - Common Terms Agreement


  (a)

observe all applicable entity procedures necessary to maintain its separate existence and formalities, including:

 

  (i)

maintaining minutes or records of meetings of the members and/or managers of the Obligor;

 

  (ii)

acting on behalf of itself only pursuant to due authorization of the members and/or managers, including, when applicable, any independent managers or members; and

 

  (iii)

conducting its own business in its own name and through authorized agents pursuant to its Constitutional Documents;

 

  (b)

allocate fairly and reasonably any shared expenses, including overhead for shared office space or common employees (if any);

 

  (c)

use separate stationery, invoices and checks bearing its own name;

 

  (d)

prepare and maintain its own full and complete books, accounting records (including books of account and payroll, if any) and other documents and records, in each case which are separate and apart from the books, accounting records and other documents and records of the Sponsor or any Affiliate thereof (other than the other Obligor);

 

  (e)

maintain separate bank accounts in its own name or otherwise pursuant to the Finance Documents and make all investments by or on behalf of an Obligor solely in its name except as otherwise provided by the Finance Documents;

 

  (f)

separate its property and not allow funds or other assets to be commingled with the funds and other assets of, held by, or registered in the name of the Sponsor or any Affiliate thereof (other than the other Obligor), and maintain its assets in such a manner that it is not costly or difficult to identify or ascertain such assets, all except to the extent otherwise provided by the Finance Documents;

 

  (g)

not hold itself out as being liable for the debts of the Sponsor or any Affiliate thereof (other than the other Obligor) and not guarantee the debts of the Sponsor or any Affiliate thereof (other than the other Obligor) except as permitted by the Finance Documents;

 

  (h)

not acquire or assume obligations or securities of, or make loans or advances to, any of its Affiliates except as required under the Finance Documents;

 

  (i)

maintain separate financial statements, showing its assets and liabilities separate and apart from those of any other Person, and not have its assets

 

-93-

Calcasieu Pass - Common Terms Agreement


 

listed on the balance sheet of any other Person; provided that such Obligor may also report its financial statements on a consolidated or combined basis with one or more of its Affiliates in accordance with GAAP so long as appropriate notation is made on such consolidated financial statements to indicate the separateness of the Obligors from such Affiliate(s) and to disclose the separate nature of the Obligors’ Indebtedness;

 

  (j)

prepare and file its own tax returns separate from those of any Person except to the extent that the Obligor is treated as a “disregarded entity” for tax purposes and is not required to file tax returns under applicable law;

 

  (k)

pay its own liabilities and expenses out of its own assets (except as provided under the Finance Documents);

 

  (l)

maintain adequate capitalization in light of its contemplated business and obligations;

 

  (m)

hold itself out to third parties as a legal entity, separate and distinct and independent from any other entity, conduct its own business solely under its name and correct any known misunderstanding as to the separateness of the Obligors from any other Person; and

 

  (n)

have and maintain Constitutional Documents which comply with the requirements of this Section 12.24 (Separateness),

provided that no limitation in this Section 12.24 (Separateness) shall apply to the Obligors as among one another.

 

  12.25

Historical DSCR

 

  (a)

The Obligors shall not permit the Historical DSCR as of the end of any fiscal quarter from and following the First Repayment Date to be less than 1.15:1.

 

  (b)

Notwithstanding anything in clause (a) above to the contrary, if the Historical DSCR at the end of any fiscal quarter following the First Repayment Date is less than 1.15:1 but greater than 1:1, any direct or indirect owner of the Obligors shall have the right to provide cash to the Obligors not later than ten Business Days following the delivery of the calculation of such Historical DSCR in the form of equity contributions or Subordinated Debt in order to increase the Historical DSCR to 1.15:1; provided that such right may not be exercised for more than two consecutive fiscal quarters nor, with respect to each Senior Debt Instrument, more than four (4) times over the term of such Senior Debt Instrument.

 

-94-

Calcasieu Pass - Common Terms Agreement


  12.26

Auditors

The Borrower shall engage Deloitte LLP and shall not replace such auditor except with another independent certified public accounting firm of recognized national standing.

 

  12.27

Gas Transportation Arrangements; Gas Purchase Arrangements

 

  (a)

The Borrower shall comply in all material respects with the gas sourcing plan attached as Schedule K (Gas Sourcing Plan) hereto, as may be updated (i) by the Borrower on a semi-annual basis in relation to the list of Qualified Gas Suppliers as set forth in the definition thereof or (ii) from time to time otherwise by mutual agreement by the Borrower and the Intercreditor Agent (acting on the instruction of the Requisite Intercreditor Parties, whose consent to updates of such gas sourcing plan shall not be unreasonably withheld, conditioned or delayed if determined to be reasonable by the Market Consultant and/or Independent Engineer, as appropriate).

 

  (b)

The Borrower shall deliver to the Intercreditor Agent and the Credit Facility Agent quarterly reports summarizing firm natural gas supply and transport capacity and associated volumes.

 

  12.28

Insurance Covenant

 

  (a)

To the extent available to the Obligors on Reasonable Commercial Terms and taking into account requirements of applicable law and regulation, the Obligors shall obtain and maintain, or cause to be obtained and maintained, at all times, the commercial insurance coverage set forth in Schedule L (Schedule of Minimum Insurance) hereto describing the minimum insurance required to be held by the Obligors (the “Schedule of Minimum Insurance”). “Reasonable Commercial Terms” means commercial insurance market terms which are reasonable having regard to the nature of the risk insured, the cost of maintaining insurance against that risk and the interests of the Obligors and the Secured Parties under the Finance Documents. Without prejudice to any other element, the cost of maintaining insurance alone is not a determinant of Reasonable Commercial Terms. Disputes as to whether the relevant insurance is available on Reasonable Commercial Terms, is in accordance with applicable laws or regulations or complies with the Schedule of Minimum Insurance shall be referred to an independent insurance expert from the agreed list of independent insurance experts attached as Schedule M (Independent Insurance Experts) hereto, as such list may be updated from time to time by mutual agreement by the Borrower and the Intercreditor Agent.

 

-95-

Calcasieu Pass - Common Terms Agreement


  (b)

With respect to all Mortgaged Property located in a special flood hazard area (as defined pursuant to applicable flood insurance regulations), the Borrower will obtain and maintain at all times flood insurance for all Collateral located on such property as may be required under the Flood Program and will provide to each Facility Lender evidence of compliance with such requirements as may be reasonably requested by such Lender. The timing and process for delivery of such evidence will be as set forth in the Schedule of Minimum Insurance. If any Building (as defined in the applicable flood insurance regulations) or Manufactured (Mobile) Home (as defined in the applicable flood insurance regulations) constitutes property that is secured for the benefit of the Senior Creditors pursuant to a mortgage required under the Finance Documents, the Borrower shall maintain in full force and effect flood insurance for such property, structures and contents in such amount and for so long as required by applicable flood insurance regulations.

 

  (c)

The Borrower will provide forty-five (45) days prior written notice to the Intercreditor Agent and each Facility Agent before it commences construction of any Building (as defined in the applicable flood insurance regulations) after the Closing Date and before it affixes any Manufactured (Mobile) Home (as defined in the applicable flood insurance regulations) after the Closing Date to any property that is secured for the benefit of the Senior Creditors pursuant to a mortgage required under the Finance Documents and that is located in a special flood hazard area (as defined pursuant to applicable flood insurance regulations). The preceding sentence will not affect the obligations of the Borrower under Section 12.28(b) (Insurance Covenant) above to maintain flood insurance.

 

  (d)

The Borrower will provide forty-five (45) days prior written notice to the Intercreditor Agent before it acquires any Real Estate that is permitted under the Finance Documents and that will be secured for the benefit of the Senior Creditors pursuant to a deed of trust required under the Finance Documents. The preceding sentence will not affect the obligations of the Borrower under Section 12.28(b) above to maintain flood insurance.

 

  12.29

Certain Real Property Rights; Real Property Documents; Leases

 

  (a)

Each Obligor shall obtain appropriate releases, consents, crossing agreements or other like acknowledgements from the holders of the rights set forth on Schedule V (Schedule of Certain Real Property Rights) to the extent necessary for the Development.

 

  (b)

Each Obligor shall comply with its material contractual obligations under each Real Property Document then in effect to which it is a party, and, subject to Section 12.5(e) (Material Project Agreements), enforce against all other Persons that are parties thereto such Obligor’s material rights and material covenants and obligations under such Real Property Document.

 

-96-

Calcasieu Pass - Common Terms Agreement


  (c)

No Obligor shall agree to any amendment or modification of, or waiver relating to, any Real Property Document to which it is a party that could reasonably be expected to have a Material Adverse Effect or that would materially breach the terms of the Finance Documents.

 

  12.30

Margin Regulation

No Obligor shall use any portion of the proceeds of the Loans to purchase or carry any Margin Stock or to extend credit to others for the purpose of purchasing or carrying any Margin Stock. No Obligor shall use the proceeds of the Loans in a manner that could reasonably be expected to violate or be inconsistent with the provisions of Regulation T, Regulation U or Regulation X.

 

  12.31

Further Assurances

Each of the Obligors shall take all action reasonably required to preserve the validity, perfection and priority of the Liens purported to be granted to the Collateral Agent for the benefit of the Secured Parties pursuant to the Security Documents (subject to Permitted Liens). The Borrower shall promptly perform or cause to be performed any and all acts and execute or cause to be executed any and all documents (including UCC financing statements and UCC continuation statements):

 

  (a)

as are reasonably requested by the Collateral Agent for filing under the provisions of the UCC or any other Government Rule that are necessary or reasonably advisable to maintain in favor of the Collateral Agent, for the benefit of the Secured Parties, Liens on the Collateral that are duly perfected in accordance with all applicable Government Rules for the purposes of perfecting the first priority Lien (subject to Permitted Liens) created, or purported to be created, in favor of the Collateral Agent or the Secured Parties under this Agreement or any other Finance Documents;

 

  (b)

as are reasonably requested by the Collateral Agent for the purposes of ensuring the validity, enforceability and legality of this Agreement or any other Finance Document and the rights of the Secured Parties and the Collateral Agent hereunder or thereunder;

 

  (c)

as are reasonably requested by the Collateral Agent for the purposes of enabling or facilitating the proper exercise of the rights and powers granted to the Secured Parties and the Collateral Agent under this Agreement or any other Finance Document; or

 

  (d)

as are reasonably requested by the Collateral Agent to carry out the intent of, and transactions contemplated by, this Agreement and the other Finance Documents.

 

-97-

Calcasieu Pass - Common Terms Agreement


  12.32

As-Built Survey

Within 120 days after the Project Completion Date, Borrower shall deliver to the Intercreditor Agent an as-built survey of the LNG Facility Site and the LNG Facility located on it in accordance with and meeting all requirements and information required for the initial survey referred to in Section 4.1(j)(i) (Conditions to Closing Date and Initial Advance – Real Property).

 

  12.33

ERISA

The Obligors shall not establish, maintain, contribute to or become obligated to contribute to any Pension Plan or Multiemployer Plan.

 

13.

CONSULTANTS

 

  13.1

Appointment of Consultants

The common Independent Engineer, the common Insurance Advisor, the common Environmental Consultant and the common Market Consultant (the “Consultants”), as of the date hereof, are listed in Schedule N (Senior Creditors’ Advisors and Consultants) hereto. Each such Consultant shall be deemed to be retained by, and shall be solely responsible to and for the benefit of, the Facility Lenders. The Consultants may also act for the benefit of, and deliver reports to, the Indenture Trustee, Senior Noteholders, the Intercreditor Agent and/or the initial purchasers of the Senior Notes.

 

  13.2

Replacement and Fees

 

  (a)

In accordance with the terms of each such Consultant’s engagement letter, the Borrower (with the consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties, such consent not to be unreasonably withheld, conditioned or delayed) or the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties and, subject to clause (b) below, following good faith consultation with the Borrower, may remove from time to time any one or more of such Consultants, and the Borrower shall engage such replacements as the Intercreditor Agent, acting on the instructions of the Requisite Intercreditor Parties, may choose (with the prior consent of the Borrower, such consent not to be unreasonably withheld, conditioned or delayed). Such replacement is subject to confirmation at the time of its appointment of no conflict of interest that would prevent a replacement Consultant from acting for the Facility Lenders. The replacement of any Consultant shall not increase the annual limits referred to in clause (c) below.

 

  (b)

Notwithstanding clause (a) above, in the event that a Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing that is reasonably connected to a matter on which a

 

-98-

Calcasieu Pass - Common Terms Agreement


 

Consultant may be requested by the Senior Creditors or their representatives to advise, for the duration of such default, the Borrower’s consent rights under such clause (a) above shall cease and the Intercreditor Agent, acting reasonably on the instructions of the Requisite Intercreditor Parties, shall have the right to remove any Consultant and appoint a replacement Consultant.

 

  (c)

All fees and expenses of the Consultants (whether the original ones or replacements) shall, subject in each case to the applicable Consultant’s engagement letter, be paid by the Borrower. Any reasonable fees incurred by any Consultant to provide services required under the Finance Documents but not otherwise within the scope of work under the applicable engagement letter shall be paid by the Borrower subject to certain annual limits, if any, to be specified in such engagement letter (except that such annual limits shall not apply in relation to any work (i) investigating a Loan Facility Event of Default or Unmatured Loan Facility Event of Default, or (ii) in respect of any waiver request by the Borrower, both of which instead shall be subject to reasonable work plans, budgets and compensation limits to be agreed by such Consultant in consultation with the Intercreditor Agent and advised to the Borrower). Except in such cases, the consent of the Borrower (such consent not to be unreasonably withheld, conditioned or delayed) shall be required for a Consultant to perform additional work not otherwise contemplated by the terms of the relevant engagement letter or that would otherwise cause the reasonable fees and expenses of such Consultant to exceed the annual limits set forth in the relevant engagement letter.

 

  13.3

Access

 

  (a)

After the Closing Date, Site visits to the Project Facilities may be conducted in accordance with clause (b) below upon reasonable prior request by:

 

  (i)

the Independent Engineer and, if requested, the Facility Agent (or one alternative representative) for each Senior Creditor Group comprised of Facility Lenders, any such visits to be coordinated between the Independent Engineer and the applicable Facility Agents up to two (2) times (which shall be reasonably spaced within the applicable period) per calendar year, except to the extent additional visits are made in connection with the occurrence of a Loan Facility Event of Default or an Unmatured Loan Facility Event of Default; and

 

  (ii)

any Consultant to the extent reasonably required for such Consultant to provide any report, certificate or confirmation explicitly contemplated by the terms of the Finance Documents.

 

-99-

Calcasieu Pass - Common Terms Agreement


  (b)

Site visits shall be granted during normal business hours, in a manner that does not unreasonably disrupt the construction or operation of the Project Facilities in any respect, and subject to the confidentiality provision of Section 12.6 (Confidentiality) of the Common Security and Account Agreement and Section 23.7 (Confidentiality) below and reasonable safety arrangements and shall be at the cost and expense of the Obligors.

 

14.

CONDITIONS TO COMPLETION; PROJECT COMPLETION DATE WATERFALL

 

  14.1

Conditions to Occurrence of the Project Completion Date

The occurrence of the Project Completion Date is subject to the satisfaction of each of the following, and no other, common conditions (or waiver thereof by the Intercreditor Agent (acting on the instruction of the Requisite Intercreditor Parties)):

 

  (a)

Notice of Project Completion

Receipt by the Intercreditor Agent of a duly executed and completed notice of project completion from the Borrower certifying that the conditions in this Section 14.1 (Conditions to Occurrence of the Project Completion Date) have been met.

 

  (b)

Borrower Certificate

Receipt by the Intercreditor Agent of a certificate of the Borrower certifying that:

 

  (i)

each of the Repeated Representations of the Obligors is true and correct in all material respects, except for representations and warranties that are qualified by materiality or Material Adverse Effect, which shall be true and correct in all respects, on and as of the Project Completion Date as if made on and as of such date (or, if stated to have been made solely as of an earlier date, as of such earlier date);

 

  (ii)

no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing on such date or is expected to result from the occurrence of the Project Completion Date;

 

  (iii)

no default by an Obligor exists under any Material Project Agreement that could reasonably be expected to have a Material Adverse Effect and, to the Knowledge of each Obligor, no default by a Material Project Counterparty exists under any Material Project Agreement that could reasonably be expected to have a Material Adverse Effect;

 

-100-

Calcasieu Pass - Common Terms Agreement


  (iv)

to the Knowledge of each Obligor, no event of force majeure (as defined in the applicable Material Project Agreement) has occurred and is Continuing under any Material Project Agreement, the consequences of which could reasonably be expected to have a Material Adverse Effect; and

 

  (v)

(i) the Required LNG SPAs (including guarantees or other forms of credit support required by their terms), (ii) the Pipeline Service Agreements, (iii) the Gas Transportation Agreements (or Replacement Material Contract in respect thereof) (iv) the Service Agreements described in clauses (a) through (e) of the definition thereof (or Replacement Material Contract in respect thereof) and (v) the Gas Supply Agreement and the gas supply agreements that collectively are sufficient to enable the Borrower to meet its obligations under the Required LNG SPAs are, in each case, in full force and effect, enforceable against the parties thereto in accordance with such contract’s terms, except as limited by general principles of equity and bankruptcy, insolvency and similar laws.

 

  (c)

Physical Completion Certificate

Receipt by the Intercreditor Agent of a certificate from the Independent Engineer confirming:

 

  (i)

that Facility Substantial Completion (as such term is defined in the EPC Contract) has occurred pursuant to the EPC Contract (subject to the completion of any punch list items under the EPC Contract);

 

  (ii)

the applicable performance tests under each of the Material Construction Contracts have been successfully passed in accordance with such Material Construction Contract;

 

  (iii)

the Lenders’ Reliability Test has been passed in accordance with the test criteria set out in Schedule O (Lenders’ Reliability Test Criteria)hereto and the “LRT Completion Certificate” contemplated thereby has been delivered to the Intercreditor Agent; and

 

  (iv)

the Borrower’s calculation of the Permitted Completion Costs and that the Borrower has reserved an amount sufficient for the Permitted Completion Costs; and

 

  (v)

the Project Facilities are Operational.

 

-101-

Calcasieu Pass - Common Terms Agreement


  (d)

Commercial Operation Date

Receipt by the Intercreditor Agent of a duly executed certificate of the Borrower certifying that the Commercial Operation Date under each of the Required LNG SPAs then in effect has timely occurred and deliveries of LNG under each Required LNG SPA have commenced in accordance with such Required LNG SPA.

 

  (e)

Payment

Receipt by the Collateral Agent of evidence that the Borrower shall have paid all amounts due and payable under each of the Material Construction Contracts other than: (i) the Permitted Completion Amount, which is on deposit in the Construction Account after giving effect to the deposits and transfers set forth in Section 4.5(c) (Deposits and Withdrawals –Construction Account) of the Common Security and Account Agreement, (ii) amounts properly withheld or retained by the Borrower in accordance with the terms and conditions of such Material Construction Contracts, (iii) any bonus or other amounts payable under such Material Construction Contracts after Final Completion and (iv) in the event that any amount under any Material Construction Contract is disputed by the Borrower, reserved amounts adequate for payment thereof.

 

  (f)

Title Policy Endorsement

Receipt by the Intercreditor Agent of a Disbursement Endorsement meeting the requirements set forth in the definition thereof for the delivery of such endorsement on the Project Completion Date.

 

  (g)

Insurance

Receipt by the Intercreditor Agent of a certificate from the Borrower (confirmed in writing to be reasonable by the Insurance Advisor) confirming that all insurance premium payments due and payable as of the Project Completion Date have been paid and that the insurance then in place is in effect and complies with the then-applicable requirements of Schedule L (Schedule of Minimum Insurance) hereto, and certificates of insurance, binders or other documentation evidencing such insurance.

 

  (h)

Permits

Receipt by the Intercreditor Agent of evidence that all material Permits necessary for the Development (as set forth on Schedule F (Material Permits)) (and, in the case of any Export Authorization, such Export Authorization to the extent that it is a Required Export Authorization):

 

  (i)

have been obtained and are in full force and effect;

 

-102-

Calcasieu Pass - Common Terms Agreement


  (ii)

are held in the name of an Obligor or such third party as set forth on Schedule F (Material Permits) hereto and as allowed pursuant to applicable law or regulations;

 

  (iii)

are not the subject of any pending appeal (or if subject to any appeal, such appeal does not have a reasonable probability of success and the applicable permit remains effective during such appeal) and all applicable fixed time periods for appeal set forth in the Government Rules pursuant to which such Permits were issued have expired or are Permits that do not have limits on appeal periods under applicable law or regulation); and

 

  (iv)

are free from conditions or requirements (A) the compliance with which could reasonably be expected to have a Material Adverse Effect or (B) that the applicable Obligor does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development except to the extent that failure to so satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect.

 

  (i)

Project Placed in Service

Receipt by the Intercreditor Agent of evidence that the Obligors have received from FERC a notice, order or other written communication authorizing it to place the Project Facilities in service, and that the Project Facilities shall have been placed in service.

 

  (j)

Construction Contract Liquidated Damage Deposits

All Delay Liquidated Damages and Performance Liquidated Damages that were due and payable as of the Project Completion Date under each Material Construction Contract (excluding any damages that are the subject of a dispute) in excess of five ($5) million, shall have been deposited into the appropriate Account(s) and applied as set forth in the Common Security and Account Agreement.

 

  (k)

Lien Waivers

Receipt by the Intercreditor Agent of: (i) copies of Lien Waivers as have then been (and only to the extent) required pursuant to each Material Construction Contract; (ii) copies of one or more notices of termination of work filed pursuant to the Louisiana Private Works Act in the mortgage records of Cameron Parish, Louisiana, certifying termination of the work under the EPC Contract, including the installation, testing and start-up of equipment supplied to the Borrower pursuant to other Material Construction Contracts (other than those Material Construction Contracts referred to in clause (iii) of this Section 14.1(k) (Conditions to Occurrence

 

-103-

Calcasieu Pass - Common Terms Agreement


of Project Completion Date – Lien Waivers)); (iii) copies of one or more notices of termination of work filed pursuant to the Louisiana Private Works Act in the mortgage records of Cameron Parish, Louisiana, certifying termination of the work under the Material Construction Contracts described in clauses (b), (f), (g) and (h) of the definition thereof; and (iv) a lien certificate by the recorder of mortgages of Cameron Parish, Louisiana, issued after the period for filing a statement of claim or privilege under the Louisiana Private Works Act has expired and confirming that no statements of claim or privilege are of record (other than Permitted Liens).

 

  (l)

Initial Operating Budget

The Intercreditor Agent shall have received the initial Operating Budget required pursuant to Section 10.5 (Operating Budget).

 

  (m)

Notes

The Intercreditor Agent shall have received copies of the promissory notes requested by the Credit Facility Lenders pursuant to the Credit Facility Agreement duly authorized, executed and delivered by the Borrower.

 

  (n)

Senior Facilities Debt Service Reserve Account

The Senior Facilities Debt Service Reserve Account shall have been funded in an amount equal to the Senior Facilities Reserve Amount.

 

  (o)

Letter of Credit Reimbursement

The Borrower shall have repaid any outstanding LC Reimbursement Payments and/or Working Capital Loans.

 

  (p)

Senior Debt/Equity Ratio

The Senior Debt/Equity Ratio shall be no greater than 75:25, as certified by the Borrower.

 

  (q)

Additional Material Project Agreements

The Intercreditor Agent shall have received copies of any Material Project Agreements and required material Permits entered into or issued after the Closing Date, to the extent not previously delivered by the Borrower to the Intercreditor Agent.

 

  14.2

Project Completion Date Waterfall

 

  (a)

Preliminary Determination

 

-104-

Calcasieu Pass - Common Terms Agreement


The Intercreditor Agent and the Credit Facility Agent shall have received (i) a preliminary determination (together with reasonably detailed calculations therefor) at least 15 Business Days prior to the proposed Project Completion Date and (ii) a final determination (together with reasonably detailed calculations therefor) at least five (5) Business Days prior to the proposed Project Completion Date, in each case, of the amount of the final advance of Term Loans and the payments and transfers to be applied pursuant to Section 14.2(c) (Project Completion Date Waterfall), in each case, in form and substance reasonably satisfactory to the Credit Facility Agent acting in consultation with the Independent Engineer.

(b) Final Advance of Term Loans

On the day that is one (1) Business Day prior to the Project Completion Date and assuming all conditions to the Project Completion Date have been met or waived as of such day, and the Borrower has given a notice to the Intercreditor Agent requesting such final Advance at least three (3) Business Days prior to such day, the full remaining undrawn amount of the Contingency Reserve Term Loan Commitment, if any, shall be funded by the Secured Parties holding Contingency Reserve Term Loan Commitments and deposited into the Contingency Reserve Account.

(c) Project Completion Date Waterfall

On the Project Completion Date, amounts on deposit in the Contingency Reserve Account (i) shall be transferred to the Construction Account pursuant to Section 4.5(k)(iii) (Deposits and Withdrawals – Contingency Reserve Account) of the Common Security and Account Agreement and (ii) shall be applied in the following order of priority:

(A) first, to pay all outstanding Project Costs that are then due and payable;

(B) second, to pay all Debt Service then due and payable, if any;

(C) third, to reserve in the Completion Reserve Account an amount equal to the Permitted Completion Amount;

(D) fourth, to fund the Senior Facilities Debt Service Reserve Account in an amount equal to the Senior Facilities Reserve Amount (to the extent not funded, at the option of the Borrower, with one or more Acceptable Letters of Credit, and taking into account any Acceptable Letters of Credit or other cash already on deposit therein);

(E) fifth, to make a mandatory prepayment in respect of the Term Loans pursuant to Section 3.4(a)(ix) (Mandatory Prepayments – Contingency Reserve Amount) in an amount equal to 75% of the proceeds of any Term Loans on deposit in the Contingency Reserve Account (including the proceeds of any Term Loans funded in respect of the Contingency Reserve Term Loan Commitments pursuant to Section 14.2(b) (Project Completion Date Waterfall – Final Advance of Term Loans)) that have not been applied pursuant to clauses (A) through (D) of this Section 14.2(c); and

 

-105-

Calcasieu Pass - Common Terms Agreement


(F) sixth, to the extent any cash remains on deposit in the Construction Account (other than the Permitted Completion Amount), to make the Project Completion Date Distribution.

 

15.

LOAN FACILITY EVENTS OF DEFAULT

 

  15.1

Loan Facility Events of Default

Except as may be set forth in a Facility Agreement with respect solely to such Facility Agreement, the following events, and no others, shall be Loan Facility Events of Default:

 

  (a)

Payment Default

 

  (i)

The Borrower fails to pay principal amounts due under the Finance Documents; provided that if failure to pay occurs due to a purely administrative error, the Borrower shall have three Business Days to cure such failure; or

 

  (ii)

the Borrower fails to pay interest or any other Senior Debt Obligations due under the Finance Documents within three Business Days after those amounts become due.

 

  (b)

Breach of Project Representations and Warranties

 

  (i)

Any representation or warranty made by any Obligor in Article 5 (Representations and Warranties of the Obligors), or any representation, warranty or statement in any certificate, financial statement or other document furnished by any Obligor pursuant to this Agreement, is false when made and if such falsity is capable of being corrected or cured, is not corrected or cured within 60 days after the earlier of (A) the applicable Obligor, becoming aware of such falsity and (B) notice from the Intercreditor Agent to the Borrower, and such falsity or the adverse effects therefrom could reasonably be expected to have a Material Adverse Effect.

 

  (ii)

Any representation or warranty made by the Pledgor in the Security Document referred to in Section 3.3 (Security Interests to be Granted by Pledgor) of the Common Security and Account Agreement is false when made and such falsity is not corrected or cured within 60 days after the earlier of (A) the Borrower becoming aware of such falsity and (B) notice from the Intercreditor Agent to the Borrower, and such falsity or the adverse effects therefrom could reasonably be expected to have a Material Adverse Effect.

 

-106-

Calcasieu Pass - Common Terms Agreement


  (c)

Breach of Certain Covenants

Except as specifically provided for in another Loan Facility Event of Default in this Section 15.1 (Loan Facility Events of Default):

 

  (i)

breach by an Obligor of any covenant described in Article 6 (Incurrence of Additional Senior Debt), Section 7.1(a) (Permitted Development Expenditures), Section 7.2 (Expansion Contracts), Section 8.3 (Amendment of LNG SPAs), Section 9.1 (Change Orders), Section 12.1 (Use of Proceeds), Sections 12.2(a) or (b) (Maintenance of Existence, Franchises, Etc.), Sections 12.5(g) or (k) (Material Project Agreements), Section 12.14 (Limitation on Indebtedness), Section 12.15 (Guarantees), Section 12.16 (Limitation on Liens), Section 12.17 (Sale of Project Property), Section 12.18 (Merger, Division and Liquidation and Sale of All Assets), Section 12.19 (Limitation on Investments and Loans) or Section 12.30 (Margin Regulation);

 

  (ii)

breach of Section 12.25 (Historical DSCR) that is not cured within ten Business Days as set forth in Section 12.25 (Historical DSCR);

 

  (iii)

breach by an Obligor of any covenant described in:

 

  (1)

Section 12.2(c) (Maintenance of Existence, Franchises, Etc.) ;

 

  (2)

Section 12.6 (Compliance with Law);

 

  (3)

Section 12.7 (Environmental Compliance);

 

  (4)

Section 12.5 (Material Project Agreements) clause (b), (c), (d), (e), or (f) (but excluding covenants therein as they may apply to termination of any LNG SPA); or

 

  (5)

Section 12.13 (Taxes);

in each case with respect to the events in this sub-clause (iii) that is not corrected or cured within 30 days following the earlier of (x) the applicable Obligor becoming aware of such failure and (y) notice from the Intercreditor Agent to the Borrower;

 

  (iv)

material breach by Pledgor of any covenant contained in the Pledge Agreement that is not corrected or cured within 30 days after the earlier of (A) Pledgor becoming aware of such failure; and (B) notice from the Intercreditor Agent to the Borrower and Pledgor;

 

  (v)

(A) breach by an Obligor of:

 

-107-

Calcasieu Pass - Common Terms Agreement


  (1)

Section 12.3 (Project Construction; Maintenance of Properties);

 

  (2)

Section 12.4 (Books and Records; Inspection Rights);

 

  (3)

Section 12.20 (Nature of Business);

 

  (4)

Section 12.27 (Gas Transportation Arrangements; Gas Purchase Arrangements); or

 

  (5)

Section 12.21 (Transactions with Affiliates); or

 

  (B)

material breach by a Obligor of any other covenant in Article 12 (Obligor Covenants) (except for the covenants described in Section 12.8 (Permits) and Section 12.10 (FERC Order), which are subject to clause (p) (Loan Facility Events of Default – Permits Generally) below) or any other covenant in this Agreement, the Security Documents, or with respect to any Facility Lender, its Facility Agreement; and

in each case, with respect to the events in this sub-clause (v), that is not corrected or cured within 60 days after the earlier of (1) the applicable Obligor becoming aware of such breach; and (2) notice from the Intercreditor Agent to the Borrower, such cure period to be extended to a total of 90 days so long as the breach is subject to cure, such Obligor is diligently pursuing a cure and such additional cure period could not reasonably be expected to result in a Material Adverse Effect.

 

  (d)

Bankruptcy

 

  (i)

a Bankruptcy with respect to an Obligor or the Pledgor has occurred; or

 

  (ii)

a Bankruptcy with respect to the Specified Counterparty has occurred.

 

  (e)

Abandonment

Abandonment has occurred and is continuing.

 

  (f)

Destruction

All or a material part of the Project Facilities is destroyed, lost or damaged, unless there is reasonably expected to be sufficient proceeds of insurance (available for such purpose and permitted to be applied in accordance with the terms of the Finance Documents) committed or

 

-108-

Calcasieu Pass - Common Terms Agreement


otherwise available Equity Funding or other funds available to cure such destruction, loss or damage.

 

  (g)

Event of Taking

An Event of Taking of (i) all or substantially all of the Project Facilities or (ii) that could reasonably be expected to have a Material Adverse Effect has occurred.

 

  (h)

Security Interests Invalid

Any of the Security Interests over a material portion of the Collateral cease to be validly perfected (subject to applicable Reservations) in favor of the Collateral Agent on behalf of the Secured Parties, and five (5) Business Days have elapsed after the Collateral Agent or Intercreditor Agent gave notice to the Borrower thereof.

 

  (i)

Unsatisfied Judgments

Any one or more of final judgments in excess of $100 million in the aggregate against an Obligor (or against any other Person where an Obligor is liable to satisfy such judgment), in each case such amounts to be measured net of Insurance Proceeds which are reasonably expected to be paid and, in each case, such judgment or judgments remain unpaid, unstayed on appeal, undischarged, unbonded or undismissed for a period of 60 days after the date of entry of such judgment.

 

  (j)

Unenforceability or Termination of Finance Documents

Any of the Finance Documents (other than (x) a Direct Agreement in respect of any LNG SPA that is not a Required LNG SPA then in full force and effect or (y) any Direct Agreement in the case where the occurrence of a Loan Facility Event of Default has been triggered by an event affecting the underlying Material Project Agreement or a Senior Debt prepayment remedy or other Loan Facility Event of Default is applicable under the Finance Documents) or any material provision thereof:

 

  (i)

is expressly repudiated in writing by any party thereto (other than the Collateral Agent, the Account Bank, the Intercreditor Agent or any Facility Lender);

 

  (ii)

shall have been terminated (other than pursuant to the terms thereof following discharge in full of all obligations thereof or otherwise by agreement in writing of the parties thereto not as a result of a Loan Facility Event of Default hereunder); or

 

-109-

Calcasieu Pass - Common Terms Agreement


  (iii)

is declared unenforceable in a final judgment of a court of competent jurisdiction against any party (other than the Collateral Agent, the Account Bank, the Intercreditor Agent or any Facility Lender) and such unenforceability is not cured (subject to any applicable Reservations) within five (5) Business Days following the date of entry of such judgment; provided that such five- Business Day period shall apply only so long as the relevant party is attempting in good faith to cure such unenforceability.

 

  (k)

Unenforceability or Termination of Material Project Agreements:

Any Material Project Agreement or any material provision thereof:

 

  (i)

is expressly repudiated in writing by any party;

 

  (ii)

is declared unenforceable in a final judgment of a court of competent jurisdiction against any party and such unenforceability is not cured (subject to any applicable Reservations) within 60 days following the date of entry of such judgment;

 

  (iii)

shall have been terminated (other than pursuant to the terms thereof following discharge in full of all obligations thereof or otherwise by agreement in writing of the parties thereto); or

 

  (iv)

shall at any time for any reason cease to be valid and binding or in full force and effect;

provided that, in each case of sub-clauses (i) and (ii) above there could reasonably be expected to be a Material Adverse Effect as a result thereof (without regard, for such purpose, to clause (a) of the definition of Material Adverse Effect); provided further that, in respect of sub-clause (ii) above, such 60 day period shall apply only so long as the relevant party is attempting in good faith to cure such unenforceability;

provided further that, in each case of sub-clauses (iii) and (iv) above, any such case shall not give rise to a Loan Facility Event of Default if, (i) in case of any termination of an LNG SPA, the Obligors enter into a Replacement Material Contract within 90 days of such termination, such cure period to be extended to a total of 180 days so long as the breach is subject to cure, such Obligor is diligently pursuing a cure and such additional cure period could not reasonably be expected to result in a Material Adverse Effect and (ii) in case of any termination of any other Material Project Agreement, the Obligors enter into a Replacement Material Contract within 60 days of such termination, such cure period to be extended to a total of 90 days so long as the breach is subject to cure, such Obligor is diligently pursuing a cure and such additional cure period could not reasonably be expected to result in a Material Adverse Effect, in each case in accordance with the requirements of Section 12.5(g) (Material Project Agreements).

 

-110-

Calcasieu Pass - Common Terms Agreement


  (l)

Failure to Achieve Project Completion Date by Date Certain

The Project Completion Date does not occur by the Date Certain.

 

  (m)

Cross Acceleration (other Indebtedness)

A default has occurred with respect to Indebtedness (other than (i) Indebtedness secured by the Security Documents and (ii) Subordinated Debt) of any Obligor that exceeds a principal amount of $100 million and such default has continued beyond any applicable grace period, and its effect has been to cause the entire amount of such Indebtedness to become due and such Indebtedness remains unpaid or the acceleration of its stated maturity remains unrescinded.

 

  (n)

Cross Acceleration (Senior Notes)

In respect of any Senior Notes outstanding, if applicable, acceleration of such Senior Notes following an Indenture Event of Default, without prejudice to any Loan Facility Event of Default under clause (a) (Loan Facility Events of Default – Payment Default) above that may be triggered by a breach under any Indenture.

 

  (o)

Reserved

 

  (p)

Permits Generally

From and after the Closing Date, any Permit required under Section 12.8 (Permits), Section 12.9 (Export Authorizations) or Section 12.10 (FERC Order) related to the Borrower or the Development is Impaired and such Impairment could reasonably be expected to have a Material Adverse Effect, unless:

 

  (i)

the Borrower provides a reasonable remedial plan (which sets forth in reasonable detail the proposed steps to be taken to cure such Impairment) no later than 30 days following the date that the Borrower has Knowledge of the occurrence of such Impairment;

 

  (ii)

the Borrower diligently pursues the implementation of such remedial plan; and

 

  (iii)

such Impairment is cured no later than 90 days following the occurrence thereof (or such longer period, if any, presented by any administrative, legal, regulatory or statutory time period applicable thereto but only as may be reasonably necessary to cure such

 

-111-

Calcasieu Pass - Common Terms Agreement


 

Impairment or required by a Governmental Authority; provided that the Borrower shall have no more than 180 days in the aggregate to cure such Impairment).

 

  (q)

ERISA

 

  (i)

On or after the Closing Date, an ERISA Event has occurred and is continuing and such event, whether individually or in the aggregate, could reasonably be expected to result in a Material Adverse Effect; or

 

  (ii)

the aggregate “amount of unfunded benefit liabilities” (within the meaning of Section 4001(a)(18) of ERISA) under all Plans determined in accordance with Title IV of ERISA could reasonably be expected to result in a Material Adverse Effect.

 

  (r)

Change of Control

A Change of Control has occurred and is continuing.

 

  15.2

Declaration of Loan Facility Declared Default

 

  (a)

A Loan Facility Declared Default occurs upon delivery to the Borrower (with a copy to the Collateral Agent), after any applicable grace or cure period has expired, of a certificate from the Intercreditor Agent stating that any Loan Facility Event of Default has occurred and is Continuing and declaring a Loan Facility Declared Default.

 

  (b)

A Loan Facility Declared Default also shall be deemed to have occurred and been declared without the delivery of such a certificate or such declaration or any other notice upon the occurrence of a Loan Facility Event of Default referred to in Section 15.1(d)(i) (Loan Facility Events of Default Bankruptcy).

 

  15.3

Cessation of Loan Facility Declared Default

The Intercreditor Agent shall promptly notify the Collateral Agent, the Borrower and each Facility Lender upon learning of the cessation of the Loan Facility Event of Default to which such certificate(s) related (such notice, a “Cessation Notice”). Upon delivery of a Cessation Notice, the applicable Loan Facility Declared Default shall be deemed not to be Continuing.

 

  15.4

Instruction to Intercreditor Agent

Any Senior Creditor Group Representative may deliver an instruction to the Intercreditor Agent to deliver a certificate stating that any Loan Facility Event of Default has occurred and Requisite Intercreditor Parties may deliver an instruction

 

-112-

Calcasieu Pass - Common Terms Agreement


to the Intercreditor Agent to deliver a Cessation Notice; provided that in the case of a Loan Facility Event of Default that arises solely under an individual Facility Agreement, such instruction to declare a Loan Facility Event of Default or a cessation of a Loan Facility Event of Default to the Intercreditor Agent may be given only by the Senior Creditor Group Representative representing the Facility Lenders under such Facility Agreement (and not any other Senior Creditor Group Representatives).

 

16.

COMMON REMEDIES AND ENFORCEMENT

 

  16.1

Facility Lender Remedies for Loan Facility Declared Events of Default

 

  (a)

Enforcement Action

Subject to clause (b) (Facility Lender Remedies for Loan Facility Declared Events of Default – Initiating Percentage for Enforcement Action with Respect to Collateral) below and the Common Security and Account Agreement, upon the occurrence and Continuation of a Loan Facility Declared Default, based on the instruction procedures described in clause (b) (Facility Lender Remedies for Loan Facility Declared Events of Default – Initiating Percentage for Enforcement Action with Respect to Collateral) below, rights and remedies (each, an “Enforcement Action”) may be exercised on behalf of the Facility Lenders under their Facility Agreement, including the following:

 

  (i)

suspension of undrawn Facility Debt Commitments under the Facility Agreements;

 

  (ii)

termination of undrawn Facility Debt Commitments and acceleration of all Senior Debt Obligations under the Facility Agreements;

 

  (iii)

directing the Collateral Agent to take control of the Secured Accounts and apply the balances in accordance with Section 4.7 (Cash Waterfall) of the Common Security and Account Agreement; and

 

  (iv)

subject to clause (b) (Facility Lender Remedies for Loan Facility Declared Events of Default – Initiating Percentage for Enforcement Action with Respect to Collateral) below, requesting the Collateral Agent to exercise all rights with respect to the Security Interests and apply the proceeds from the enforcement of Security Interests.

 

  (b)

Initiating Percentage for Enforcement Action with Respect to Collateral

 

-113-

Calcasieu Pass - Common Terms Agreement


Upon a Loan Facility Declared Default, the Required Intercreditor Parties shall have the right to instruct the Intercreditor Agent who shall in turn request the Collateral Agent (and confirm in writing to the Collateral Agent that such instruction has been given pursuant to this Agreement and Intercreditor Agreement) to take Enforcement Action pursuant to the Common Security and Account Agreement; provided that upon an Event of Default under Section 15.1(d) (Loan Facility Events of Default – Bankruptcy), all Senior Debt Obligations under Loans shall be accelerated automatically and shall immediately become due and payable, without presentment, demand, protest or other notice or action of any kind, all of which are expressly waived by the Obligors.

 

  16.2

Remedies for Events of Default under Facility Agreements

At any time after the occurrence of any Loan Facility Event of Default that is not listed in Section 15.1 (Loan Facility Events of Default) of this Agreement but arises only under an individual Facility Agreement, the relevant Facility Agent may, subject to the terms and conditions of this Agreement, the Common Security and Account Agreement and the Intercreditor Agreement, exercise the express remedies available to it in accordance with such Facility Agreement and shall promptly notify each other Facility Agent, the Borrower and the Intercreditor Agent thereof.

 

  16.3

Permitted Actions under Common Security and Account Agreement

Nothing in this Article 16 (Common Remedies and Enforcement) shall limit or restrict any right of any Secured Party or the Collateral Agent pursuant to Section 6.3 (Conduct of Security Enforcement Action) of the Common Security and Account Agreement.

 

17.

INTERCREDITOR ARRANGEMENTS

 

  17.1

Facility Agents; Facility Lender Action

 

  (a)

Each of the Facility Agents hereby represents that it has been duly appointed pursuant to the applicable Facility Agreement to represent the applicable Facility Lender(s) that is a lender or are lenders under such Facility Agreement and is entitled to vote and give instructions to the Intercreditor Agent (and, where applicable, to act thereunder) on behalf of the Facility Lender(s) that is a lender or are lenders under such Facility Agreement.

 

  (b)

Each Facility Agent shall, for purposes of this Agreement, act in its capacity as “Facility Agent” under the applicable Facility Agreement and shall, for purposes of the Common Security and Account Agreement, act in the capacity of Senior Creditor Group Representative on behalf of the Facility Lender(s) that is a lender or are lenders under the applicable

 

-114-

Calcasieu Pass - Common Terms Agreement


Facility Agreement (each such group of Facility Lender(s) under an individual Facility Agreement being a “Senior Creditor Group” for purposes of the Common Security and Account Agreement).

 

  (c)

Notwithstanding anything herein to the contrary, where any Facility Agent exercises any right or discretion, makes any Decision or determination or performs any obligation under this Agreement, references to “Facility Agent” in such circumstances shall mean “Facility Agent acting pursuant to instructions from its Facility Lender(s) in accordance with the Intercreditor Agreement or the applicable Facility Agreement, as the case may be.”

 

  (d)

Notwithstanding anything herein to the contrary, where:

 

  (i)

the Intercreditor Agent exercises any right or discretion, makes any Decision or determination or performs any obligation under this Agreement, references to “Intercreditor Agent” in such circumstances shall mean “Intercreditor Agent acting pursuant to instructions from Requisite Intercreditor Parties as may be required in accordance with the Intercreditor Agreement”; and

 

  (ii)

a Facility Agent, in its capacity as such or as a Senior Creditor Group Representative, makes any Decision or determination or performs any obligation under this Agreement, references to “Facility Agent” and “Senior Creditor Group Representative” in such circumstances shall mean such “Facility Agent” or “Senior Creditor Group Representative”, in each case acting pursuant to instructions from requisite Facility Lenders as may be required in accordance with its Facility Agreement and, if applicable, the Intercreditor Agreement.

 

  17.2

Agreement to Comply with Intercreditor Agreement

The Intercreditor Agent agrees for the benefit of the Borrower that, in discharging its duties as Intercreditor Agent, it shall act at all times in accordance with the terms of the Intercreditor Agreement and the Common Security and Account Agreement as they may be amended from time to time, and which shall include, for the avoidance of doubt, the obtaining of the consent of the Borrower to any replacement Intercreditor Agent to the extent required herein or therein.

 

  17.3

Agreement Not to Amend Entrenched Intercreditor Provisions

The Intercreditor Agent and the Facility Agents agree not to Modify the following provisions of the Intercreditor Agreement unless otherwise agreed in writing by the Borrower (in the addition to the agreement of any other party that is required under the Intercreditor Agreement):

 

-115-

Calcasieu Pass - Common Terms Agreement


  (a)

Article 1 (Definitions and Interpretation);

 

  (b)

Section 2.2 (Intercreditor Agent’s Rights and Obligations);

 

  (c)

Section 2.4(d) (Defaults);

 

  (d)

Sections 2.7(a) and (b) (Resignation of Intercreditor Agent);

 

  (e)

Section 2.8 (Removal of Intercreditor Agent);

 

  (f)

Section 3.1 (Decision Making);

 

  (g)

Section 3.2 (Voting Generally: Intercreditor Party Decisions and Intercreditor Votes);

 

  (h)

Section 3.3 (Intercreditor Votes: Each Party’s Entitlement to Vote);

 

  (i)

Section 3.4 (Casting of Votes);

 

  (j)

Section 3.6 (Other Voting Considerations);

 

  (k)

Section 3.7 (Voting by Hedging Banks);

 

  (l)

Section 3.8 (Voting by Sponsor and its Affiliates);

 

  (m)

Section 4.1 (100% Voting Issues);

 

  (n)

Section 4.2 (Special Voting Issues);

 

  (o)

Section 4.3 (Majority Voting Issues);

 

  (p)

Section 4.4 (Administrative Decisions);

 

  (q)

Section 4.6 (Individual Senior Creditor Group Decisions);

 

  (r)

Article 5 (Agreement of Hedging Banks);

 

  (s)

Section 6.1 (Governing Law);

 

  (t)

Section 7.2 (Amendment);

 

  (u)

Section 7.12 (Third-party Beneficiaries);

 

  (v)

Schedule 1 (All Loan Facilities Decisions); and

 

  (w)

Schedule 2 (Administrative Decisions).

 

-116-

Calcasieu Pass - Common Terms Agreement


18.

THE INTERCREDITOR AGENT

 

  18.1

Intercreditor Agreement

Pursuant to and in accordance with the Intercreditor Agreement, the Facility Lenders have appointed the Intercreditor Agent to, among other things, act as their agent under and in connection with this Agreement and the Intercreditor Agreement and any other Finance Document to which the Intercreditor Agent (in such capacity) is a party.

 

  18.2

Relationship

 

  (a)

The Intercreditor Agent shall in no respect be the agent of the Borrower by virtue of this Agreement.

 

  (b)

The Intercreditor Agent shall not be liable to the Borrower for any breach by any Person (other than for the Intercreditor Agent’s own gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final and non-appealable judgment), or be liable to any Person for any breach by the Borrower, of this Agreement or any of the Finance Documents.

 

  18.3

Delivery of Documentation

Executed counterparts of each of the Finance Documents have been delivered to the Intercreditor Agent on, or prior to, the Closing Date and the Intercreditor Agent has acknowledged receipt thereof. Each of the Parties hereto agrees to deliver to the Intercreditor Agent executed counterparts of any Permitted Hedging Instrument or any Senior Debt Instrument relating to Replacement Senior Debt or Working Capital Debt and of any instrument amending or modifying any agreement previously delivered to the Intercreditor Agent.

 

  18.4

Liability

The Intercreditor Agent shall not be responsible to the Borrower for:

 

  (a)

the execution (other than its own execution), genuineness, validity, adequacy, enforceability, admissibility in evidence or sufficiency of any Finance Document or any other document;

 

  (b)

the collectability of amounts payable under any Finance Document; and

 

  (c)

the adequacy, accuracy and/or completeness of any statements (whether written or oral) made in, or in connection with, any Finance Document, with the exception of any statements made with respect to itself.

 

-117-

Calcasieu Pass - Common Terms Agreement


  18.5

Exoneration

 

  (a)

Without limiting clause (b) of this Section 18.5 below, the Intercreditor Agent (including its officers, employees, agents and attorneys) shall not be liable to the Borrower for any action taken or not taken by it under, or in connection with, this Agreement or any other Finance Document unless directly caused by its gross negligence, fraud or willful misconduct as determined by a final non-appealable judgment of a court of competent jurisdiction.

 

  (b)

The Borrower may not bring any proceedings against any officer, employee, agent or attorney of the Intercreditor Agent in respect of any claim it might have against it or in respect of any act or omission of any kind (including gross negligence, fraud or willful misconduct) by that officer, employee or agent in relation to this Agreement or any other Finance Document. Without prejudice to the provisions of the preceding sentence of this clause (b), the restriction against taking proceedings set out in the preceding sentence of this clause (b) is not and shall not be construed as a waiver of any claim based on the conduct of such officer, employee or agent.

 

  18.6

Reliance

 

  (a)

The Intercreditor Agent shall be entitled to rely conclusively on the list of authorized signatories of the Obligors delivered to it pursuant to Section 4.1(k) (Conditions to Closing Date and Initial Advance – Bank Regulatory Requirements) (with such written updates to such authorized signatories (certifying the names and true signatures of any new authorized signatories) as may be notified by the Obligors to the Intercreditor Agent from time to time).

 

  (b)

The Facility Lenders shall communicate to the Intercreditor Agent only through the relevant Facility Agent.

 

  18.7

Resignation and Succession

 

  (a)

The Borrower acknowledges that, subject to and in accordance with the terms and conditions of the Intercreditor Agreement, the Intercreditor Agent may resign and a successor Intercreditor Agent shall be appointed in accordance with the terms of the Intercreditor Agreement.

 

  (b)

The resignation of the Intercreditor Agent and the appointment of any successor in that capacity shall both become effective only upon the satisfaction of the applicable conditions set out in the Intercreditor Agreement. On satisfaction of such conditions, the successor Intercreditor Agent shall succeed to the position of the Intercreditor Agent under this

 

-118-

Calcasieu Pass - Common Terms Agreement


  Agreement and the term “Intercreditor Agent” shall include the successor Intercreditor Agent.

 

  (c)

Upon its resignation becoming effective, Section 18.5(a) (Exoneration) and this Section 18.7 (Resignation and Succession) shall continue to benefit a retiring Intercreditor Agent in respect of any action taken or not taken by it under or in connection with this Agreement and the other Finance Documents while it was an Intercreditor Agent, and it shall have no further obligations under this Agreement and the other Finance Documents.

 

19.

CHANGES TO THE PARTIES

 

  19.1

Represented Parties; Successors and Assigns

Each Facility Agent represents that it is authorized on behalf of itself and on behalf of each Facility Lender under its Facility Agreement to enter into this Agreement. This Agreement is binding on the successors, permitted transferees and assigns of each Party.

 

  19.2

Transfers by the Obligors

The Obligors may not assign or transfer any of their rights or obligations under this Agreement without the prior written consent of the Intercreditor Agent, and any such attempted assignment or transfer without such prior written consent shall be void and invalid.

 

  19.3

Replacement of Facility Agents

 

  (a)

Any Facility Agent may be replaced by the Facility Lender(s) under the relevant Facility Agreement in accordance with the terms of such Facility Agreement, pursuant to which such Facility Agent was appointed and the Borrower, the Intercreditor Agent and each other Facility Agent shall be notified in writing promptly of any such replacement.

 

  (b)

No replacement Facility Agent shall become a Facility Agent under this Agreement unless and until:

 

  (i)

the resignation in writing of the Facility Agent being replaced has been delivered to the Borrower, the Intercreditor Agent and each other Facility Agent;

 

  (ii)

a “Replacement Facility Agent Accession Agreement” substantially in the form set forth in Schedule P – 1 (Replacement Facility Agent Accession Agreement) has been executed and delivered to the Intercreditor Agent; and

 

-119-

Calcasieu Pass - Common Terms Agreement


  (iii)

such Replacement Facility Agent Accession Agreement, when delivered to the Intercreditor Agent, is accompanied by one or more certificates as to the due authorization, execution and delivery of the Replacement Facility Agent Accession Agreement and incumbency of the officers or attorneys-in-fact who executed the Replacement Facility Agent Accession Agreement.

 

  (c)

The Intercreditor Agent shall, as soon as reasonably practicable, after receiving (A) a duly completed and executed Replacement Facility Agent Accession Agreement which appears on its face to comply with the terms of this Agreement; and (B) all of the documents required to be delivered to it pursuant to this Section 19.3 (Replacement of Facility Agents):

 

  (i)

countersign such Replacement Facility Agent Accession Agreement by way of acceptance thereof;

 

  (ii)

deliver to the Borrower and each Facility Agent the notice referred to in Section 8 (Effective Date) of such Replacement Facility Agent Accession Agreement;

 

  (iii)

amend the Register kept by the Intercreditor Agent pursuant to Section 19.7 (Register) accordingly; and

 

  (iv)

deliver such revised Register to the Borrower and each Facility Agent.

 

  (d)

Upon the Intercreditor Agent delivering to the Borrower and each Facility Agent the notice referred to in Section 8 (Effective Date) of such Replacement Facility Agent Accession Agreement, the Facility Agent shall become (if not already) a party to this Agreement.

 

  19.4

Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement

 

  (a)

If the Borrower incurs, pursuant to this Agreement, Additional Senior Debt permitted by and in accordance with Article 6 (Incurrence of Additional Senior Debt), then each Facility Agent in respect of such Additional Senior Debt to be appointed pursuant to the applicable Facility Agreement(s) shall accede to this Agreement on behalf of itself and on behalf of the Facility Lenders under the Facility Agreement in respect of which the Additional Senior Debt is incurred.

 

  (b)

No Facility Agent to be appointed pursuant to Facility Agreements in respect of Additional Senior Debt shall become a Facility Agent under this Agreement, and therefore no Facility Lender under a Facility Agreement in respect of Additional Senior Debt incurred pursuant to this Agreement shall become a Facility Lender under this Agreement, unless and until:

 

-120-

Calcasieu Pass - Common Terms Agreement


  (i)

a “New Facility Agent Accession Agreement (Additional Senior Debt)” substantially in the form set forth in Schedule P – 2 (New Facility Agent Accession Agreement (Additional Senior Debt)) shall have been executed and delivered to the Intercreditor Agent, in which, among the other provisions set forth in such New Facility Agent Accession Agreement (Additional Senior Debt), the relevant Facility Agent agrees (i) on behalf of itself to become a party to this Agreement and to represent the Facility Lenders under the relevant Facility Agreement and to be bound by all of the terms and conditions of this Agreement and (ii) on behalf of the Facility Lenders under the Facility Agreement in respect of which the Additional Senior Debt is incurred, to become a party to this Agreement and to be bound by all of the terms and conditions of this Agreement; and

 

  (ii)

such New Facility Agent Accession Agreement (Additional Senior Debt), when delivered to the Intercreditor Agent, shall have been accompanied by one or more certificates as to the due authorization, execution and delivery of the New Facility Agent Accession Agreement (Additional Senior Debt) and incumbency of the officers or attorneys-in-fact who executed the New Facility Agent Accession Agreement (Additional Senior Debt).

 

  (c)

The Facility Agent representing the Facility Lenders providing the Additional Senior Debt referred to in in this Section 19.4 (Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement) shall, concurrently with acceding to this Agreement pursuant to this Section 19.4 (Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement), accede to (A) the Common Security and Account Agreement in accordance with Section 2.2 (Incremental Senior Debt) of the Common Security and Account Agreement and (B) the Intercreditor Agreement.

 

  (d)

A copy of the related Facility Agreements shall be attached to the New Facility Agent Accession Agreement (Additional Senior Debt) as an exhibit.

 

  (e)

The Intercreditor Agent shall, as soon as reasonably practicable, after receiving (A) a duly completed and executed New Facility Agent Accession Agreement (Additional Senior Debt) which appears on its face to comply with the terms of this Agreement and the Intercreditor Agreement; and (B) all of the documents required to be delivered to it pursuant to this Section 19.4 (Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement):

 

  (i)

countersign such New Facility Agent Accession Agreement (Additional Senior Debt) by way of acceptance thereof;

 

-121-

Calcasieu Pass - Common Terms Agreement


  (ii)

deliver to the Borrower and each Facility Agent the notice referred to in Section 8 (Effective Date) of such New Facility Agent Accession Agreement (Additional Senior Debt) (if applicable);

 

  (iii)

amend the Register kept by the Intercreditor Agent pursuant to Section 19.7 (Register) accordingly; and

 

  (iv)

deliver such revised Register to the Borrower and each Facility Agent.

 

  (f)

Upon the Intercreditor Agent delivering to the Borrower and each Facility Agent the notice referred to in Section 8 (Effective Date) of such New Facility Agent Accession Agreement (Additional Senior Debt), the Facility Agent on its own behalf and on behalf of the Facility Lenders under its Facility Agreement shall become party to this Agreement in such capacity.

 

  19.5

Mitigation Obligations; Replacement of Lenders

 

  (a)

If any Facility Lender requires the Borrower to pay any Indemnified Taxes or additional amounts to any Facility Lender or any Governmental Authority for the account of any Facility Lender pursuant to Article 21 (Tax Gross-Up and Indemnities) or requests compensation under Section 22.1 (Increased Costs), then such Facility Lender (at the request of the Borrower) shall use commercially reasonable efforts to designate a different lending office for funding or booking its Loans under the Finance Documents or to assign its rights and obligations hereunder to another of its offices, branches or Affiliates or take any other reasonable steps not inconsistent with any applicable legal or regulatory restrictions or the internal policies of such Facility Lender that it would otherwise take in similar circumstances under comparable provisions of other financing agreements if, in the reasonable judgment of such Facility Lender, such designation or assignment (i) would eliminate or reduce amounts payable pursuant to Article 21 (Tax Gross-Up and Indemnities) or Section 22.1 (Increased Costs), as applicable, in the future, and (ii) would not subject such Facility Lender to any unreimbursed cost or expense and would not otherwise, in the reasonable opinion of such Facility Lender, be disadvantageous or prejudicial to such Facility Lender. The Borrower hereby agrees to pay and/or indemnify any Facility Lender for all reasonable costs and expenses incurred by such Facility Lender in connection with any such designation or assignment.

 

  (b)

If any Facility Lender reasonably determines that any Change in Law has made it unlawful, or if any Governmental Authority has asserted after the Closing Date that it is unlawful, for such Facility Lender or its applicable lending office to fund or maintain its Loans (an “Illegality Event”), such Facility Lender shall, in good faith consultation with the Borrower, take

 

-122-

Calcasieu Pass - Common Terms Agreement


  all reasonable steps to mitigate any circumstances which arise and which would result in any amount becoming payable under or pursuant to, or cancelled pursuant to, Section 3.4(a)(vi) (Mandatory Prepayments Illegality), including transferring its rights and obligations under the Finance Documents to another Affiliate or lending office and, to the extent applicable, converting its outstanding Loans as permitted under the relevant Facility Agreement; provided that this clause (b) in no way limits the obligations of the Borrower under any of the Finance Documents. If, notwithstanding its obligations under this clause (b), such Facility Lender is unable to fund or maintain its Loans as a result of such Illegality Event, the Facility Lender shall promptly notify its Facility Agent upon becoming aware of that Illegality Event, which notice shall set forth in reasonable detail all relevant information about such Illegality Event, and such Facility Agent shall promptly notify and provide such information to the Intercreditor Agent, who shall forward such notice to the Borrower.

 

  (c)

Subject to clause (d) below, if:

 

  (i)

(A) the Borrower is required to pay any Indemnified Taxes or additional amounts to any Facility Lender or any Governmental Authority for the account of any Facility Lender pursuant to clause (a) above or (B) any Facility Lender requests compensation under clause (a) above, and, in each case, such Facility Lender has declined or is unable to designate a different lending office or assign its rights and obligations to another of its offices, branches or Affiliates or take any other reasonable steps in accordance with clause (a) above;

 

  (ii)

any Facility Lender notifies the Borrower of an Illegality Event pursuant to clause (b) above;

 

  (iii)

any Facility Lender becomes a Defaulting Lender; or

 

  (iv)

any Facility Lender becomes a Non-Consenting Lender,

then the Borrower may, at its sole expense and effort, upon notice to such Facility Lender and its Facility Agent as provided herein, require such Facility Lender to assign and delegate, without recourse (in accordance with and subject to the restrictions contained in, and consents required by the applicable Facility Agreement), all of its interests, rights (other than its existing rights to payments pursuant to Article 21 (Tax Gross-Up and Indemnities) or Section 22.1 (Increased Costs), as applicable) and obligations under the applicable Facility Agreement and the related Finance Documents to an Acceptable Lender that shall assume such obligations (which assignee may be another Facility Lender, if a Facility Lender accepts such assignment); provided that:

 

-123-

Calcasieu Pass - Common Terms Agreement


  (I)

such Facility Lender shall have received payment of an amount equal to the Senior Debt Obligations due and payable to such Facility Lender at the time from such assignee (to the extent of such outstanding principal and accrued interest and fees) or the Borrower (in the case of all other amounts);

 

  (II)

in the case any such assignment resulting from a claim for indemnification under Article 21 (Tax Gross-Up and Indemnities), such assignment shall result in a reduction in such payment of Indemnified Taxes or additional amounts to any Facility Lender or any Governmental Authority for the account of any Facility Lender thereafter;

 

  (III)

in the case of any such assignment resulting from a claim for compensation under Section 22.1 (Increased Costs), such assignment will result in a reduction in such compensation thereafter;

 

  (IV)

such assignment may be made on a non pro rata basis to existing or non-affected Facility Lenders but otherwise subject to Section 3.6 (Prepayment Fees and Breakage Costs) and the transfers terms of the applicable Facility Agreement;

 

  (V)

such assignment does not conflict with applicable law or regulations;

 

  (VI)

in the case of any assignment resulting from a Facility Lender becoming a Non-Consenting Lender, the applicable assignee shall have consented to the applicable amendment, waiver or consent; and

 

  (VII)

the Borrower shall have paid to the Facility Agent the assignment fee (if any).

 

  (d)

A Facility Lender shall not be required to make any such assignment or delegation pursuant to clause (c) above if, prior thereto, as a result of a waiver by such Facility Lender or otherwise, the circumstances entitling the Borrower to require such assignment and delegation pursuant to clause (c) above cease to apply. Notwithstanding the satisfaction of each of the conditions set forth in Article 21 (Tax Gross-Up and Indemnities) or Section 22.1 (Increased Costs), a Facility Lender shall have the right to refuse to be replaced pursuant to sub-clause 19.5(c)(i) above; provided that the Borrower shall no longer be obligated to pay such Facility Lender any of the compensation or additional amounts incurred or accrued under Article 21 (Tax Gross-Up and Indemnities) or Section 22.1 (Increased Costs) from and after the date that such replacement would have occurred but for such Facility Lender’s refusal.

 

-124-

Calcasieu Pass - Common Terms Agreement


  (e)

As a condition of the right of the Borrower to remove any Facility Lender pursuant to this Section 19.5 (Mitigation Obligations; Replacement of Lenders), the Borrower shall either:

 

  (i)

arrange for the assignment or novation of any Permitted Hedging Instruments with such Facility Lender or any of its Affiliates simultaneously with such removal; or

 

  (ii)

terminate the applicable Permitted Hedging Instruments and pay any relevant Hedging Termination Amount.

 

  19.6

Transfers by a Facility Lender

Facility Lenders with rights or obligations under this Agreement or any other Finance Documents to which it is a party (in its capacity as a Facility Lender) (an “Existing Facility Lender”) may not assign or transfer, novate or otherwise dispose of any of their rights or obligations in existence at such time except in accordance with the relevant Facility Agreement, and any attempted assignment or transfer without complying with the provisions of this Section 19.6 (Transfers by a Facility Lender) shall be void and invalid.

 

  19.7

Register

The Facility Agent under each Facility Agreement shall maintain a register of Lenders under such Facility Agreement in accordance with the terms and conditions of the relevant Facility Agreement (the “Register”).

 

  19.8

Resulting Increased Costs

If:

 

  (a)

any assignment or transfer of all or any part of the rights and/or obligations of a Facility Lender pursuant to this Agreement and the applicable Facility Agreement; or

 

  (b)

any change in a Facility Lender’s facility office from that described in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement,

would, but for this Section 19.8 (Resulting Increased Costs), result, as a consequence of circumstances which are prevailing at that time, in the Borrower being obliged to pay any incurred costs (whether as a result of increased costs, illegality or fees in respect of Security Documents, Direct Agreements or perfection of security interests or similar provisions, except as a result of the tax

 

-125-

Calcasieu Pass - Common Terms Agreement


gross-ups provided for under Article 21 (Tax Gross-Up and Indemnities)) or indemnities which would not have been payable if such assignment, novation, transfer or change of office had not occurred, then, unless such assignment, novation, transfer or change in facility office was made at the request of the Borrower in accordance with mitigation provisions of the Finance Documents, the Facility Lender shall only be entitled to receive those amounts to the extent that such amounts would have been payable in connection with the Existing Facility Lender or the Existing Facility Lender’s facility office had the assignment, transfer or change in facility office not occurred.

 

20.

SUBORDINATION

 

  20.1

Subordination

 

  (a)

The Parties hereto agree that to the extent that the Sponsor or any Affiliate thereof, or any other Person:

 

  (i)

has provided Subordinated Debt to the Obligors prior to the Closing Date, each Obligor shall procure (to the extent that they did not so procure on the Closing Date) that such Sponsor, such Affiliate or other Person, as applicable, lending it such Subordinated Debt shall enter into a Subordination Agreement substantially in the form included in Schedule S – 1 (Form of General Subordination Agreement) hereto simultaneously with and as a condition to the Obligors’ entry into this Agreement; and

 

  (ii)

intends to provide Subordinated Debt to the Obligors after the Closing Date, each Obligor shall require that the Sponsor, such Affiliate or other Person, as applicable, lending it such Subordinated Debt shall enter into as a condition precedent to providing such Subordinated Debt a Subordination Agreement substantially in the form included in Schedule S – 1 (Form of General Subordination Agreement) hereto.

 

  (b)

The Parties hereto agree that the Obligors shall enter into a subordination agreement substantially in the form included in Schedule S – 2 (Form of Obligor Subordination Agreement)) hereto on or prior to the date hereof, which shall apply to any Indebtedness any Obligor may from time to time be owed by any other Obligor.

 

21.

TAX GROSS-UP AND INDEMNITIES

 

  21.1

Withholding Tax Gross-Up

Any and all payments by or on account of any obligation of the Borrower under or in connection with any Finance Document shall be made without deduction or withholding for any Taxes, except as required by applicable law. If any applicable

 

-126-

Calcasieu Pass - Common Terms Agreement


law (as determined in the good faith discretion of the Borrower or the relevant Facility Agent, as applicable) requires the deduction or withholding of any Tax from any such payment by the Borrower or the applicable Facility Agent, then the Borrower or the applicable Facility Agent shall make such deduction or withholding and shall timely pay the full amount deducted or withheld to the relevant Governmental Authority in accordance with applicable law and, if such Tax is an Indemnified Tax, then the sum payable by the Borrower shall be increased as necessary so that after such deduction or withholding has been made (including such deductions and withholdings applicable to additional sums payable under this Article 21 (Tax Gross-Up and Indemnities)), the relevant Finance Party receives an amount equal to the sum it would have received had no such deduction or withholding been made.

 

  21.2

Payment of Other Taxes

The Borrower shall timely pay to the relevant Governmental Authority in accordance with applicable law, or at the option of the applicable Facility Agent timely reimburse it for the payment of, any Other Taxes.

 

  21.3

Indemnification by the Borrower

The Borrower shall indemnify each Finance Party and each Facility Agent (and any of their respective Affiliates), within 20 Business Days after written demand therefor, for the full amount of any Indemnified Taxes (including Indemnified Taxes imposed or asserted on or attributable to amounts payable under this Article 21 (Tax Gross-Up and Indemnities)) payable or paid by, or required to be withheld or deducted from a payment to, such Finance Party or Facility Agent (or Affiliate) in connection with a Finance Document, and any reasonable expenses arising therefrom or with respect thereto, whether or not such Indemnified Taxes were correctly or legally imposed or asserted by the relevant Governmental Authority. A certificate as to the amount of such payment or liability delivered to the Borrower by a Finance Party (with a copy to the relevant Facility Agent), or by a Facility Agent on its own behalf or on behalf of a Finance Party, shall be conclusive absent manifest error.

 

  21.4

Indemnification by the Facility Lenders

Each Facility Lender shall severally indemnify its Facility Agent, within 20 Business Days after written demand therefor, for (a) any Indemnified Taxes attributable to such Facility Lender (but only to the extent that the Borrower has not already indemnified such Facility Agent for such Indemnified Taxes and without limiting the obligation of the Borrower to do so), (b) any Taxes attributable to such Facility Lender’s failure to comply with the provisions of Section 19.6 (Transfers by a Facility Lender) and the relevant Facility Agreement relating to the maintenance of a Participant Register and (c) any Excluded Taxes attributable to such Facility Lender, in each case, that are payable or paid by such Facility Agent in connection with any Finance Document, and any reasonable

 

-127-

Calcasieu Pass - Common Terms Agreement


expenses arising therefrom or with respect thereto, whether or not such Taxes were correctly or legally imposed or asserted by the relevant Governmental Authority. A certificate as to the amount of such payment or liability delivered to any Facility Lender by its Facility Agent shall be conclusive absent manifest error. Each Facility Lender hereby authorizes its Facility Agent to set off and apply any and all amounts at any time owing to such Facility Lender under any Finance Document or otherwise payable by such Facility Agent to the Facility Lender from any other source against any amount due to such Facility Agent under this Section 21.4 (Indemnification by the Facility Lenders).

 

  21.5

Status of Facility Lenders and Facility Agents

 

  (a)

Any Facility Lender entitled to an exemption from or reduction of withholding Tax with respect to payments made under any Finance Document shall deliver to the Borrower and its Facility Agent, at the time or times reasonably requested by the Borrower or such Facility Agent, such properly completed and executed documentation reasonably requested by the Borrower or such Facility Agent as shall permit such payments to be made without withholding or at a reduced rate of withholding. In addition, any Facility Lender, if reasonably requested by the Borrower or such Facility Agent, shall deliver such other documentation prescribed by applicable law or reasonably requested by the Borrower or such Facility Agent as shall enable the Borrower or such Facility Agent to determine whether or not such Facility Lender is subject to backup withholding or information reporting requirements. Notwithstanding anything to the contrary in the preceding two sentences, the completion, execution and submission of such documentation (other than such documentation set forth in sub-clauses 21.5(b)(i), 21.5(b)(ii) and 21.5(b)(iv) below) shall not be required if, in the Facility Lender’s reasonable judgment, such completion, execution or submission would subject such Facility Lender to any material unreimbursed cost or expense or would materially prejudice the legal or commercial position of such Facility Lender.

 

  (b)

Without limiting the generality of the foregoing:

 

  (i)

any Facility Lender that is a US Person shall deliver to the Borrower and its Facility Agent on or prior to the date on which such Facility Lender becomes a Facility Lender under the relevant Facility Agreement (and from time to time thereafter upon the reasonable request of the Borrower or such Facility Agent) executed copies of IRS Form W-9 certifying that such Facility Lender is exempt from US federal backup withholding tax;

 

  (ii)

any Facility Lender that is not a US Person shall, to the extent it is legally entitled to do so, deliver to the Borrower and its Facility Agent (in such number of copies as shall be requested by the

 

-128-

Calcasieu Pass - Common Terms Agreement


  recipient) on or prior to the date on which such Facility Lender becomes a Facility Lender under the relevant Facility Agreement (and from time to time thereafter upon the reasonable request of the Borrower or such Facility Agent) whichever of the following is applicable:

 

  (A)

in the case of a Facility Lender claiming the benefits of an income tax treaty to which the United States is a party (x) with respect to payments of interest under any Finance Document, executed copies of IRS Form W-8BEN or IRS Form W-8BEN-E establishing an exemption from, or reduction of, US federal withholding Tax pursuant to the “interest” article of such tax treaty and (y) with respect to any other applicable payments under any Finance Document, IRS Form W-8BEN or IRS Form W-8BEN-E establishing an exemption from, or reduction of, US federal withholding Tax pursuant to the “business profits” or “other income” article of such tax treaty;

 

  (B)

executed copies of IRS Form W-8ECI;

 

  (C)

in the case of a Facility Lender claiming the benefits of the exemption for portfolio interest under Section 881(c) of the Code, (x) a certificate to the effect that such Facility Lender is not a “bank” within the meaning of Section 881(c)(3)(A) of the Code, a “10 percent shareholder” of the Borrower within the meaning of Section 881(c)(3)(B) of the Code, or a “controlled foreign corporation” described in Section 881(c)(3)(C) of the Code (a “US Tax Compliance Certificate”) and (y) executed copies of IRS Form W-8BEN or IRS Form W-8BEN-E; or

 

  (D)

to the extent a Facility Lender is not the beneficial owner, executed copies of IRS Form W-8IMY, accompanied by IRS Form W-8EXP, IRS Form W-8ECI, IRS Form W- 8BEN or IRS Form W-8BEN-E, a US Tax Compliance Certificate, IRS Form W-9, and/or other certification documents from each beneficial owner, as applicable; provided that if the Facility Lender is a partnership and one or more direct or indirect partners of such Facility Lender are claiming the portfolio interest exemption, such Facility Lender may provide a US Tax Compliance Certificate on behalf of each such direct and indirect partner;

 

  (iii)

any Facility Lender that is not a US Person shall, to the extent it is legally entitled to do so, deliver to the Borrower and its Facility Agent (in such number of copies as shall be requested by the

 

-129-

Calcasieu Pass - Common Terms Agreement


  recipient) on or prior to the date on which such Facility Lender becomes a Facility Lender under the relevant Facility Agreement (and from time to time thereafter upon the reasonable request of the Borrower or such Facility Agent) executed copies of any other form prescribed by applicable law as a basis for claiming exemption from or a reduction in US federal withholding Tax, duly completed, together with such supplementary documentation as may be prescribed by applicable law to permit the Borrower or such Facility Agent to determine the withholding or deduction required to be made; and

 

  (iv)

if a payment made to a Facility Lender under any Finance Document would be subject to US federal withholding Tax imposed by FATCA if such Facility Lender were to fail to comply with the applicable reporting requirements of FATCA (including those contained in Section 1471(b) or 1472(b) of the Code, as applicable), such Facility Lender shall deliver to the Borrower and its Facility Agent at the time or times prescribed by law and at such time or times reasonably requested by the Borrower or such Facility Agent such documentation prescribed by applicable law (including as prescribed by Section 1471(b)(3)(C)(i) of the Code) and such additional documentation reasonably requested by the Borrower or such Facility Agent as may be necessary for the Borrower and such Facility Agent to comply with their obligations under FATCA and to determine whether such Facility Lender has complied with such Facility Lender’s obligations under FATCA or to determine the amount to deduct and withhold from such payment. Solely for purposes of this sub-clause (iv), “FATCA” shall include any amendments made to FATCA after the Closing Date.

 

  (c)

Any Facility Agent that is not a US Person shall provide on or prior to the date it becomes a party to the Facility Agreement executed copies of IRS Form W-8IMY, with the effect that the Borrower may make payments to the Facility Agent, to the extent such payments are received by the Facility Agent as an intermediary, without deduction or withholding of any taxes imposed by the United States.

 

  (d)

Each Facility Lender and Facility Agent agrees that if any form or certification it previously delivered expires or becomes obsolete or inaccurate in any respect, it shall update such form or certification or promptly notify the Borrower and the relevant Facility Agent in writing of its legal inability to do so.

 

-130-

Calcasieu Pass - Common Terms Agreement


  21.6

Refunds

To the extent that a Facility Lender or its Affiliate determines, in its sole discretion exercised in good faith, that it has obtained a refund or credit (in lieu of a refund) in respect of any Taxes as to which it has been indemnified pursuant to this Article 21 (Tax Gross-Up and Indemnities) (including by the payment of additional amounts pursuant to this Article 21 (Tax Gross-Up and Indemnities)), the relevant Facility Lender shall pay the Borrower an amount equal to such refund or credit, but only to the extent of indemnity payments made under this Article 21 (Tax Gross-Up and Indemnities) with respect to the Taxes giving rise to such refund or credit, and net of costs and expenses (including Taxes) and without interest (other than interest paid by the relevant Governmental Authority with respect to such refund or credit). The Borrower, upon the request of the Facility Lender or its Affiliate, shall repay to the Facility Lender or its Affiliate the amount paid over pursuant to the preceding sentence (plus any penalties, interest or other charges imposed by the relevant Governmental Authority) in the event that the Facility Lender or its Affiliate is required to repay such refund or credit to such Governmental Authority. Notwithstanding anything to the contrary in this paragraph, in no event shall the Facility Lender or its Affiliate be required to pay any amount to the Borrower pursuant to this paragraph the payment of which would place the Facility Lender or its Affiliate in a less favorable net after- Tax position than the Facility Lender or its Affiliate would have been in if the Tax subject to indemnification and giving rise to such refund or credit had not been deducted, withheld or otherwise imposed and the indemnification payments or additional amounts with respect to such Tax had never been paid. This paragraph shall not be construed to require any Facility Lender or its Affiliate to make available its Tax returns (or any other information relating to its Taxes that it deems confidential) to the Borrower or any other Person.

 

  21.7

Evidence of Payments

As soon as practicable after any payment of Taxes by any Obligor to a Governmental Authority pursuant to this Article 21 (Tax Gross-Up and Indemnities), such Obligor shall deliver to the relevant Facility Agent the original or a certified copy of a receipt issued by such Governmental Authority evidencing such payment, a copy of the return reporting such payment or other evidence of such payment reasonably satisfactory to the Facility Agent.

 

  21.8

Survival

Each Party’s obligations under this Article 21 (Tax Gross-Up and Indemnities) shall survive the resignation or replacement of any Facility Agent or any assignment of rights by, or the replacement of, a Facility Lender, the termination of the Facility Debt Commitments and the repayment, satisfaction or discharge of all obligations under any Finance Document.

 

-131-

Calcasieu Pass - Common Terms Agreement


  21.9

Defined Terms

For purposes of this Article 21 (Tax Gross-Up and Indemnities):

 

  (a)

the term “applicable law” includes FATCA;

 

  (b)

the term “Finance Document” does not include any Indenture or Senior Notes;

 

  (c)

the term “Governmental Authority” includes any government of a foreign jurisdiction; and

 

  (d)

the term “Facility Agent” includes the Intercreditor Agent and the Collateral Agent, to the extent payments hereunder in respect of Senior Debt Obligations are made to it.

 

22.

INCREASED COSTS

 

  22.1

Increased Costs

 

  (a)

If any Change in Law shall:

 

  (i)

impose, modify or deem applicable any reserve, special deposit, compulsory loan, insurance charge or similar requirement against assets of, deposits with or for the account of, or credit extended or participated in by, any Facility Lender;

 

  (ii)

subject any Finance Party (or its Affiliates) to any Taxes (other than (x) Indemnified Taxes, (y) Taxes described in clauses (b) through (d) of the definition of Excluded Taxes and (z) Connection Income Taxes) on its loans, loan principal, commitments or other obligations, or its deposits, reserves, other liabilities or capital attributable thereto; or

 

  (iii)

impose on any Facility Lender or the London interbank market any other condition, cost or expense (other than Taxes) affecting this Agreement or Loans made by such Facility Lender;

and the result of any of the foregoing shall be to increase the cost to such Finance Party of making, converting to, continuing or maintaining any Loan (or of maintaining its obligation to make any such Loan), or to reduce the amount of any sum received or receivable by such Finance Party hereunder (whether of principal, interest or any other amount) then, upon request of such Finance Party, the Borrower shall within the time period specified in clause (b) below pay to such Finance Party such additional amount or amounts as shall compensate such Finance Party for such additional costs incurred or reduction suffered (except to the extent

 

-132-

Calcasieu Pass - Common Terms Agreement


the Borrower is excused from payment pursuant to Section 19.5 (Mitigation Obligations; Replacement of Lenders) or Section 19.8 (Resulting Increased Costs)).

 

  (b)

If any Facility Lender determines that any Change in Law regarding capital or liquidity requirements has or would have the effect of reducing the rate of return on such Facility Lender’s capital or (without duplication) on the capital of such Facility Lender’s holding company, if any, as a consequence of this Agreement, the Facility Debt Commitments of such Facility Lender or the Loans made by such Facility Lender to a level below that which such Facility Lender or such Facility Lender’s holding company could have achieved but for such Change in Law (taking into consideration such Facility Lender’s policies and the policies of such Facility Lender’s holding company with respect to capital adequacy and liquidity), then from time to time upon notice by such Facility Lender, the Borrower shall pay to such Facility Lender within 30 days following the receipt of such notice by the Facility Lender such additional amount or amounts as shall compensate such Facility Lender or (without duplication) such Facility Lender’s holding company for any such reduction suffered (except to the extent the Borrower is excused from payment pursuant to Section 19.5 (Mitigation Obligations; Replacement of Lenders) or Section 19.8 (Resulting Increased Costs)).

 

  (c)

The applicable Finance Party will deliver to the Borrower (with a copy to the Intercreditor Agent) a certificate setting forth in reasonable detail the amount or amounts necessary to compensate such Finance Party or its holding company, as the case may be, as specified in clauses (a) and (b) above. The Borrower shall pay such Finance Party the amount shown as due on any such certificate within 30 days after receipt thereof. Such certificate shall be conclusive absent manifest error.

 

  (d)

Failure or delay on the part of any Finance Party to demand compensation pursuant to this Section 22.1 (Increased Costs) shall not constitute a waiver of such Finance Party’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Finance Party pursuant to this Section 22.1 (Increased Costs) for any increased costs or reductions incurred or reductions suffered more than 180 days prior to the date that such Facility Lender notifies the Borrower of the Change in Law giving rise to such increased costs or reductions, and of such Facility Lender’s intention to claim compensation therefor (except that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 180 day period referred to above shall be extended to include the period of retroactive effect thereof).

 

  (e)

Notwithstanding any other provision in this Agreement, no Facility Lender shall demand compensation pursuant to this Article 22 (Increased Costs)

 

-133-

Calcasieu Pass - Common Terms Agreement


  in respect of the Change in Law arising from the matters described in the proviso to the definition of “Change in Law” if it shall not at the time be the general policy or practice of such Facility Lender, as determined by such Facility Lender, to demand such compensation in similar circumstances under comparable provisions of other credit agreements, if any. For the avoidance of doubt, this clause (e) shall not impose an obligation on a Facility Lender to provide information regarding compensation claimed and/or paid under any other specific loan agreement; provided that such Facility Lender shall, upon request from the Borrower, provide a written confirmation to the Borrower regarding whether it is the general policy or practice of such Facility Lender, as the case may be, to demand such compensation in similar circumstances under comparable provisions of other credit agreements.

 

  22.2

Relationship Between Increased Costs and Taxes

Any compensation of a Facility Lender pursuant to Article 21 (Tax Gross-Up and Indemnities) shall be made without duplication under this Article 22 (Increased Costs) and any compensation of a Facility Lender pursuant to this Article 22 (Increased Costs) shall be made without duplication under Article 21 (Tax Gross- Up and Indemnities).

 

23.

MISCELLANEOUS

 

  23.1

Termination

 

  (a)

Upon the occurrence of the Discharge Date in respect of the Senior Debt Obligations under this Agreement and each Facility Agreement, then, subject to reinstatement as provided in clause (c) below, this Agreement shall terminate and the Intercreditor Agent shall, at the expense of the Borrower, execute and deliver a termination statement.

 

  (b)

The obligations of the Facility Lenders to make further disbursements of Loans under their respective Facility Agreements shall terminate in accordance with the applicable Facility Agreement and, in any case, upon the termination of this Agreement, and the Security Interests of such Facility Lenders shall be discharged and released pursuant to Section 12.1 (Termination) of the Common Security and Account Agreement.

 

  (c)

This Agreement shall continue to be effective or be reinstated, as the case may be, if (and only to the extent that) any payment or performance of the obligations of the Borrower hereunder is rescinded, avoided, voidable, liable to be set aside, reduced or otherwise not properly payable to, or must otherwise be returned or restored by the Intercreditor Agent, any Facility Agent, the Collateral Agent or any Facility Lender as a result of (i) Bankruptcy, insolvency, reorganization with respect to the Borrower or the Intercreditor Agent, any Facility Agent, the Collateral Agent or any

 

-134-

Calcasieu Pass - Common Terms Agreement


  Facility Lender, (ii) upon the dissolution of, or appointment of any intervenor, conservator, trustee or similar official for the Borrower, the Intercreditor Agent, any Facility Agent, the Collateral Agent or any Facility Lender or for any substantial part of the Borrower’s or any other such Person’s assets, (iii) as a result of any settlement or compromise with any Person (including the Borrower) in respect of such payment or otherwise, or (iv) any similar event or otherwise and, in such case, the provisions of Section 10.1 (Nature of Obligations) of the Common Security and Account Agreement shall apply hereto mutatis mutandis.

 

  23.2

Right of Set-Off

Each Facility Lender, each Facility Agent and the Intercreditor Agent are hereby authorized at any time and from time to time, to the fullest extent permitted by law but subject to any other provision of this Agreement and the Finance Documents, to set off and apply any and all deposits (general or special, time or demand, provisional or final) at any time held and other indebtedness at any time owing by such Facility Lender, each Facility Agent or the Intercreditor Agent, as applicable, to or for the credit or the account of any Obligor, as applicable, against the Senior Debt Obligations due and payable to such Facility Lender, such Facility Agent or the Intercreditor Agent, as applicable, at the time of such offset. If the obligations are in different currencies, the Facility Lender, the Facility Agent and the Intercreditor Agent, as applicable, may convert either obligation at a market rate of exchange in its usual course of business for the purposes of the set-off. The rights of each Facility Lender, each Facility Agent and the Intercreditor Agent under this Section 23.2 (Right of Set-Off) are in addition to other rights and remedies (including other rights of set-off) that such Facility Lender, such Facility Agent and the Intercreditor Agent, as applicable, may have. Each Facility Lender shall notify its respective Facility Agent and the Borrower forthwith upon the exercise or purported exercise of any right of set-off, giving full details in relation thereto, and such Facility Agent shall promptly inform the Intercreditor Agent in writing, who shall inform the other Facility Agents of the same. Any amounts set off by any Facility Lender in accordance with this Section 23.2 (Right of Set-Off) or under this Agreement shall be subject to the sharing arrangements set forth in Section 2.3(b) (Payments and Prepayments – Sharing of Non-Pro Rata Payments) of the Common Security and Account Agreement.

 

  23.3

Waiver of Immunity

To the extent that any Party hereto has or hereafter may acquire, or be entitled to claim for itself or its assets, any immunity from jurisdiction of any court or from any legal process (whether through service or notice, attachment in aid of execution, execution or otherwise) with respect to itself or its assets, it shall irrevocably agree not to claim and hereby irrevocably waives such immunity in respect of its obligations under the Finance Documents to which it is a party and all other documents to be executed and delivered in connection with the Finance

 

-135-

Calcasieu Pass - Common Terms Agreement


Documents to which it is a party and the transactions contemplated thereby and, without limiting the generality of the foregoing, hereby agrees that the waivers set forth in this Section 23.3 (Waiver of Immunity) shall be effective to the fullest extent permitted under applicable law.

 

  23.4

Expenses

 

  (a)

The Borrower shall pay to the Intercreditor Agent or a Facility Agent, as the case may be, within 30 days of demand (such demand being made together with copies of invoices and reasonable supporting evidence of the nature and amount of such costs), without duplication in respect of indemnity and/or reimbursement required under any other Finance Document:

 

  (i)

to the extent such expenses have not been paid by the Borrower from the proceeds of the first disbursement of Loans pursuant to Section 4.1(p) (Conditions to Closing Date and Initial Advance – Fees; Expenses), the amount of all reasonable costs and expenses (including reasonable legal fees and expenses and excluding fees of Consultants, which shall be exclusively governed by Section 13.2 (Replacement and Fees)) incurred by any Facility Lender, Facility Agent or the Intercreditor Agent in connection with the negotiation, preparation, printing, execution and/or syndication of the Finance Documents to which it is a party, based upon fee parameters (if any, including the terms of the party’s applicable engagement or commitment letter, or Facility Agreement, as the case may be) agreed between the Borrower and the relevant parties;

 

  (ii)

the amount of all reasonable costs and expenses (including reasonable legal fees and expenses and excluding fees of Consultants, which shall be exclusively governed by Section 13.2 (Replacement and Fees)) incurred by any Facility Lender, Facility Agent or the Intercreditor Agent in connection with:

 

  (A)

the negotiation, preparation and execution of any Finance Document executed after the Closing Date;

 

  (B)

any amendment, waiver or consent requested by or on behalf of the Borrower or specifically allowed by this Agreement, whether or not granted; and

 

  (C)

(C) the exercise of its powers and the performance of its duties under this Agreement and any other Finance Documents; and

 

-136-

Calcasieu Pass - Common Terms Agreement


  (iii)

the amount of all costs and expenses (including legal fees and expenses and excluding fees of Consultants, which shall be exclusively governed by Section 13.2 (Replacement and Fees)) incurred by any Facility Lender, Facility Agent or the Intercreditor Agent in connection with the enforcement or preservation of any rights under any Finance Documents.

 

  (b)

The Facility Lenders, the Facility Agents and the Intercreditor Agent, as applicable, shall inform the Borrower on a regular basis of the ongoing costs and expenses referred to in clause (a) above.

 

  (c)

Notwithstanding anything to the contrary in this Section 23.4 (Expenses), the Facility Lenders, Facility Agents and the Intercreditor Agent shall only be entitled to the reimbursement of legal fees and expenses for the use of only one law firm engaged for all of the Facility Lenders, the Facility Agents and the Intercreditor Agent in each relevant jurisdiction unless one or more of the Facility Lenders, the Facility Agents or the Intercreditor Agent incurring such fees and expenses reasonably believes that there is a reasonable likelihood of a conflict of interest between any of them (the existence of which shall be notified to the Borrower) necessitating the use of more than one law firm in any such jurisdiction, in which case the fees and expenses of one additional firm in each relevant jurisdiction.

 

  (d)

Notwithstanding anything to the contrary in this Section 23.4 (Expenses), payment of expenses by the Borrower hereunder to be made to only a certain specified Facility Lender or Facility Lenders shall be received by the Intercreditor Agent or the relevant Facility Agent solely for the benefit of such Facility Lender or Facility Lenders, and the Borrower shall also be permitted to make the payment directly to such Facility Lender or Facility Lenders.

 

  23.5

Calculation of Floating Rate Obligations

In calculating amounts to be calculated under this Agreement, other than any interest payable on Senior Debt Obligations on which interest is payable at a floating rate of interest, if a floating rate is not known for the entire period, the floating rate to be used shall be reasonably estimated by the Borrower at the time of determination thereof.

 

  23.6

Severability

Any term or provision of this Agreement or the application thereof to any circumstance that is illegal, invalid, prohibited or unenforceable (to any extent) in any jurisdiction shall, as to such jurisdiction, be ineffective to the extent of such illegality, invalidity, prohibition or unenforceability without invalidating or rendering unenforceable the remaining terms or provisions hereof or the application of such term or provision to circumstances other than those to which it

 

-137-

Calcasieu Pass - Common Terms Agreement


is held illegal, invalid, prohibited or unenforceable. Any such illegality, invalidity, prohibition or unenforceability in any jurisdiction shall not invalidate or render unenforceable such term or provision in any other jurisdiction and the Parties hereto shall enter into good faith negotiations to replace the invalid, illegal, prohibited, or unenforceable term or provision with a view to obtaining the same commercial effect as this Agreement would have had if such term or provision had been legal, valid, and enforceable. To the extent permitted by applicable laws, the Parties hereto waive any provision of law that renders any term or provision of this Agreement illegal, invalid, prohibited or unenforceable in any respect.

 

  23.7

Confidentiality

The provisions of Section 12.6 (Confidentiality) of the Common Security and Account Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

 

  23.8

Notices

 

  (a)

Except in the case of notices and other communications expressly permitted to be given by telephone, all notices and other communications provided for herein shall be in writing in the English language (or, if not available in the English language, accompanied by an English language translation of such document) and shall be delivered by hand or overnight courier service, mailed by certified or registered mail, sent by email to the address, and/or email address of the Party to whom notice is being sent set forth below or on the Register maintained by the Intercreditor Agent in accordance with Section 19.7 (Register), which Register may, at each Facility Lender’s election, include email addresses for such Facility Lender:

 

  (i)

with respect to the Obligors, the corresponding address and other notice information set forth in Schedule Q – 1 (Addresses for Notices to Obligors);

 

  (ii)

with respect to each Facility Lender and Facility Agent, to the corresponding address and other notice information set forth in Schedule Q – 2 (Addresses for Notices to Facility Agents and Facility Lenders); and

 

  (iii)

with respect to the Intercreditor Agent, to:

Mizuho Bank, Ltd., as Intercreditor Agent

1251 Avenue of the Americas

New York, NY 10020

Attention: [***]

Telephone: [***]

Email: [***]

 

-138-

Calcasieu Pass - Common Terms Agreement


  (b)

Any notice, demand, consent or approval or communication given electronically by the Intercreditor Agent in connection with a Finance Document may be given to any Finance Party that has expressly agreed that it shall accept communication of information by this method by means of the Debt Domain Website, access to which is restricted to the parties to the Finance Documents, or by other electronic means in a manner and subject to rules established by the Intercreditor Agent and agreed with the Borrower; provided that the Intercreditor Agent may set access protocols as reasonably needed to communicate confidentially with the other Secured Parties at its sole discretion.

 

  (c)

Any Party may change its address, fax number or email address for notices and other communications hereunder by notice to the other Parties. All notices and other communications given to any Party in accordance with the provisions of this Agreement shall be deemed to have been received: (i) in the case of a letter, when delivered personally or five days after it has been put into the post; (ii) in the case of a fax, when a complete and legible copy is received by the addressee; (iii) in the case of email, upon receipt by the sender of a return receipt message (provided that, in the case of sub-clause (ii) above and this sub-clause (iii), if the date of dispatch is not a Business Day or the time of dispatch is after 5:00 pm in the location of dispatch, it shall be deemed to have been received no earlier than the opening of business on the next Business Day); and (iv) in the case of a notice contemplated by clause (b) above, on the later of (x) a notice being posted on the Debt Domain Website and (y) receipt by the Intercreditor Agent of a return receipt message in respect of an email the Intercreditor Agent has sent to the relevant Party’s email address (as notified to the Intercreditor Agent in writing at least five days before any email is sent by the Intercreditor Agent or notice posted on the Debt Domain Website) notifying such Party that the notice has become available on the Debt Domain Website.

 

  (d)

Communication by one Party to any other Party may, at the election of each such Party, be by electronic mail. For the purpose of the Finance Documents, an electronic communication will be treated as being in writing. Inclusion of an email address or addresses in the notice details for a Party shall indicate that such Party elects to receive and send communications by email subject to any particular requirements relating thereto of which it has notified each other Party. The absence of the notification of an email address shall indicate that such Party does not elect to receive or send communication by email, and any email communication to it shall be deemed not to have been delivered.

 

  (e)

In the event of any change in the identity of any of the authorized officers of the Obligors referred to in the documentary evidence provided for pursuant to Section 4.1(k) (Conditions to Closing Date and Initial

 

-139-

Calcasieu Pass - Common Terms Agreement


  Advance– Bank Regulatory Requirements) and Section 4.1(l) (Conditions to Closing Date and Initial Advance – Officer’s Certificates), the relevant Obligor shall promptly notify the Intercreditor Agent in writing of such change and, at the same time, furnish to the Intercreditor Agent certified signature specimen(s) in respect of the relevant Obligor’s new authorized officer(s). The Finance Parties may rely upon and refer to certified signature specimen(s) previously received by the Intercreditor Agent until such time as the Intercreditor Agent receives notice from the relevant Obligor of such change and the relevant certified signature specimen(s) to be furnished in connection therewith.

 

  (f)

Each of the Obligors and the other Parties to this Agreement:

 

  (i)

consents to the inclusion in the Debt Domain Website of its name, its logo and a link to its website, if any;

 

  (ii)

acknowledges that the Intercreditor Agent shall issue user identifiers, passwords and other information necessary for access to the Debt Domain Website (“Access Information”) to the Borrower and the other Parties to this Agreement;

 

  (iii)

undertakes to ensure that all Access Information issued to it by the Intercreditor Agent is kept secure and confidential in accordance with Section 12.6 (Confidentiality) of the Common Security and Account Agreement;

 

  (iv)

acknowledges that the Debt Domain Website is provided “as is” and “as available” and that the Intercreditor Agent does not warrant the accuracy or completeness of the communications or the adequacy of the Debt Domain Website and expressly disclaims liability for errors or omissions in the communications;

 

  (v)

acknowledges that no warranty of any kind, express implied or statutory, including any warranty of merchantability, fitness for a specific purpose, non-infringement of third party rights or freedom from viruses or other code defects, is made by the Intercreditor Agent in connection with the communications or the Debt Domain Website; and

 

  (vi)

agrees that neither the Intercreditor Agent nor any of its officers, directors, employees, agents, advisors or representatives is liable for damages of any kind, including direct or indirect, special, incidental or consequential, or any losses or expenses (whether in tort, contract or otherwise) incurred or suffered by it or any other Person as a result of its access or use of the Debt Domain Website or inability to access or use the Debt Domain Website (other than for its own gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final and non-appealable judgment).

 

-140-

Calcasieu Pass - Common Terms Agreement


  23.9

Successors and Assigns; Benefits of Agreement

This Agreement shall be binding upon and inure to the benefit of each of the Parties hereto (and the Facility Lenders claiming through the Parties hereto) and their subsequent respective permitted successors, permitted transferees and permitted assigns, and nothing in this Agreement, in any Senior Debt Instrument, in any Permitted Senior Debt Hedging Instrument, or in any other Finance Document, express or implied, shall give to any other Person any benefit or any legal or equitable right or remedy under this Agreement (other than the Parties hereto, their respective successors, transferees and assigns permitted hereby and, to the extent expressly contemplated thereby, the shareholders, members, partners, directors, officers, employees and agents of each of the Intercreditor Agent, Facility Agents, Facility Lenders and other indemnitees under Article 21 (Tax Gross-Up and Indemnities)).

 

  23.10

Remedies

 

  (a)

Other than as stated expressly herein, no remedy under this Agreement or any other Finance Document conferred on any Finance Party is intended to be exclusive of any other remedy, and each and every such remedy shall be cumulative and shall be in addition to every other remedy given under the Finance Documents, or now or hereafter existing at law or in equity or by statute or otherwise.

 

  (b)

The amounts payable by the Borrower at any time under this Agreement or any other Finance Document shall each be a separate and independent debt and each Finance Party, except as otherwise specifically provided in this Agreement or any other Finance Document, shall be entitled to protect and enforce its rights arising out of this Agreement or any other Finance Document, and its right, pursuant to this Agreement including any applicable Facility Agreements, to cancel or suspend its commitment to provide Senior Debt Obligations and to accelerate the maturity of amounts due under its Facility Agreement, and, except as aforesaid, it shall not be necessary for any other Finance Party to consent to, or be joined as an additional party in, any proceedings for such purposes.

 

  (c)

Except as otherwise specifically provided in this Agreement or any other Finance Document, no failure on the part of any Finance Party to exercise and no delay in exercising, and no course of dealing with respect to, any right, power or privilege under this Agreement or any other Finance Document, shall operate as a waiver thereof nor shall any single or partial exercise of any right, power or privilege under any such document preclude any other or further exercise thereof or the exercise of any other right, power or privilege. No Finance Party shall be responsible for the failure of any other Finance Party to perform its obligations hereunder or under any Facility Agreement.

 

-141-

Calcasieu Pass - Common Terms Agreement


  (d)

In case any Facility Lender or the Collateral Agent or the Intercreditor Agent on behalf of the Senior Creditors shall have proceeded to enforce any right, remedy or power under and in accordance with this Agreement or any Finance Document and the proceeding for the enforcement thereof shall have been discontinued or abandoned for any reason or shall have been determined adversely to such Facility Lender, then and in every such case the relevant Obligor and the Facility Lender shall, subject to any effect of or determination in such proceeding, severally and respectively be restored to their former positions and rights hereunder and under the Finance Documents, and thereafter all rights, remedies and powers of the Facility Lenders shall continue as though no such proceeding had been taken.

 

  (e)

The rights of each Facility Lender:

 

  (i)

may be exercised as often as necessary;

 

  (ii)

are cumulative and not exclusive of its rights under general law; and

 

  (iii)

may be waived only in writing and specifically.

 

  (f)

The undertakings by, and the obligations of, the Obligors set forth in this Agreement or in the Finance Documents are for the benefit of the Secured Parties alone, in accordance with the terms thereof.

 

  23.11

Execution in Counterparts

This Agreement may be executed in any number of counterparts and by the different Parties hereto on separate counterparts, each of which when so executed and delivered shall be an original, but all the counterparts shall together constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Agreement in electronic format (e.g., “pdf” or “tif”) shall be effective as delivery of a manually executed counterpart of this Agreement.

 

  23.12

Governing Law

THIS AGREEMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK.

 

  23.13

Waiver of Jury Trial

EACH PARTY HERETO HEREBY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY AND ALL RIGHT

 

-142-

Calcasieu Pass - Common Terms Agreement


TO TRIAL BY JURY IN ANY LEGAL PROCEEDING ARISING OUT OF OR RELATING TO THIS AGREEMENT, THE FINANCE DOCUMENTS OR THE TRANSACTIONS CONTEMPLATED THEREBY.

 

  23.14

Consent to Jurisdiction

 

  (a)

All Parties to this Agreement, as contemplated by Section 23.12 (Governing Law), shall consent to the exclusive jurisdiction of the courts of the State of New York or of the United States of America for the Southern District of New York (except as otherwise specifically provided herein).

 

  (b)

Each Party hereto:

 

  (i)

hereby irrevocably consents and agrees for the benefit of the Facility Lenders that the federal or state courts in the Borough of Manhattan, the City of New York shall have jurisdiction over any legal action, suit or proceeding against it with respect to its obligations, liabilities or any other matter under or arising out of, or in connection with, this Agreement and the Loans;

 

  (ii)

irrevocably waives any objection it may now or hereafter have to the laying of venue of any action or proceeding in any such court and any claim it may now or hereafter have that any action or proceeding has been brought in an inconvenient forum; and

 

  (iii)

irrevocably consents and agrees that the submission to the jurisdiction of the federal or state courts in the Borough of Manhattan, the City of New York shall not limit the rights of the Facility Lenders to bring any action or proceeding in any other court of competent jurisdiction nor shall the bringing of any action or the taking of any proceedings in any other jurisdiction (whether concurrently or not) limit such rights, in each case, to the extent permitted by applicable law.

 

  23.15

Amendments

 

  (a)

Except as otherwise expressly provided in this Agreement (including as provided in clause (b) below), this Agreement may be amended, modified or supplemented only by an agreement in writing signed by the Borrower, the Guarantor and the Intercreditor Agent on behalf of each Facility Agent (with copies to each Facility Agent). Except as otherwise expressly provided in the relevant agreement or document, no waiver or consent of any term or condition of this Agreement or any other Finance Document in favor of the Borrower or Guarantor or any other Party hereto or thereto by any Facility Lender, its Facility Agent or the Intercreditor Agent may be given or granted by such parties except in accordance with the Intercreditor Agreement. The Facility Lenders may not agree to amend, modify or supplement this Agreement except in accordance with the Intercreditor Agreement.

 

-143-

Calcasieu Pass - Common Terms Agreement


  (b)

The written agreement contemplated in clause (a) above shall not be required:

 

  (i)

to update the Construction Budget and Schedule in accordance with Section 10.9 (Construction Budget and Schedule) in circumstances where such update does not otherwise require approval of the Requisite Intercreditor Parties;

 

  (ii)

for a successor Intercreditor Agent to accede to this Agreement in accordance with Section 18.7 (Resignation and Succession);

 

  (iii)

for a replacement Facility Agent to accede to this Agreement in accordance with Section 19.3 (Replacement of Facility Agents);

 

  (iv)

for a new Facility Agent to accede to this Agreement in accordance with Section 19.4 (Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement);

 

  (v)

to make entries on Schedule Q – 1 (Addresses for Notices to Obligors) to update any notification addresses of any Party therein or to amend the description of the relevant Obligor’s authorized and issued equity capital and name and ownership interest of the Borrower’s member;

 

  (vi)

to update Schedule F (Material Permits) in accordance with the provisions of Section 10.4(b)(x) (Construction Reports);

 

  (vii)

to update the Qualified Gas Supplier list in the Gas Sourcing Plan as set forth in Section 12.27 (Gas Transportation Arrangements; Gas Purchase Arrangements); or

 

  (viii)

to update Schedule U (Real Property Documents) to reflect new or amended Real Property Documents referenced in clause (i) of the definition thereof.

 

  23.16

Conflicts

In case of any conflict or inconsistency between the main body of this Agreement and any Facility Agreements (including any promissory note delivered thereunder), this Agreement shall control.

 

  23.17

Effectiveness

This Agreement shall come into full force and effect on the date hereof.

 

-144-

Calcasieu Pass - Common Terms Agreement


  23.18

Limitations on Liability

No claim shall be made by any Party hereto or any of their respective Affiliates against any other Party hereto or any of their Affiliates, directors, employees, attorneys or agents for any special, indirect, consequential or punitive damages (whether or not the claim therefor is based on contract, tort or duty imposed by law), in connection with, arising out of or in any way related to the transactions contemplated by this Agreement or the other Finance Documents, Material Project Agreements or any act or omission or event occurring in connection therewith; and each Party hereby waives, releases and agrees not to sue upon any such claim for any such damages, whether or not accrued and whether or not known or suspected to exist in its favor; provided that this Section 23.18 (Limitations on Liability) shall not be construed to relieve any Obligor of any obligation it may otherwise have hereunder or under any Finance Document to indemnify any Secured Party or any applicable Related Party against any claim, cost, loss, expense (including reasonable legal fees and expenses), damage or liability, sustained or incurred by or asserted against such Secured Party or Related Party.

 

  23.19

Survival of Obligations

The provisions of Article 21 (Tax Gross-Up and Indemnities), Section 22.1 (Increased Costs), Section 23.3 (Waiver of Immunity), Section 23.4 (Expenses), Section 23.7 (Confidentiality), Section 23.8 (Notices), Section 23.9 (Successors and Assigns; Benefits of Agreement), Section 23.12 (Governing Law), Section 23.13 (Waiver of Jury Trial), Section 23.14 (Consent to Jurisdiction), Section 23.16 (Conflicts) and this Section 23.19 (Survival of Obligations) shall survive the termination of this Agreement.

 

  23.20

No Fiduciary Duty

Each Finance Party and its respective Affiliates (collectively, solely for purposes of this Section 23.20 (No Fiduciary Duty) and in their capacity as a Finance Party, the “Lenders”) may have economic interests that conflict with those of the Borrower, the Guarantor, the Sponsor or any of their Affiliates. The Obligors on behalf of themselves, the Sponsor, and any Affiliate thereof respectively agree that nothing in the Finance Documents or otherwise will be deemed to create an advisory, fiduciary or agency relationship or fiduciary or other implied duty between any Lender, on the one hand, and any of the Borrower, the Guarantor, or the Sponsor or their Affiliates, on the other hand. The Obligors acknowledge and agree that (i) the transactions contemplated by the Finance Documents (including the exercise of rights and remedies hereunder and thereunder) are arm’s-length commercial transactions between the Facility Lenders, on the one hand, and the relevant Obligors, on the other hand, and (ii) in connection therewith and with the process leading thereto, (x) no Lender has assumed an advisory or fiduciary responsibility in favor of the Borrower, the Guarantor, the Sponsor or any of their Affiliates with respect to the transactions contemplated hereby (or the exercise of

 

-145-

Calcasieu Pass - Common Terms Agreement


rights or remedies with respect thereto) or the process leading thereto (irrespective of whether any Lender has advised, is currently advising or shall advise the Borrower, the Guarantor, the Sponsor or any of their Affiliates on other matters) or any other obligation of the relevant Obligor except the obligations expressly set forth in the Finance Documents and (y) each Facility Lender is acting solely as principal and not as the agent or fiduciary of the Borrower, the Guarantor, the Sponsor or any of their Affiliates or any other Person. Each of the Obligors acknowledges and agrees that it has consulted its own legal and financial advisors to the extent it deemed appropriate and that it is responsible for making its own independent judgment with respect to such transactions and the process leading thereto. Each of the Obligors agrees that it shall not claim that any Lender has rendered advisory services of any nature or respect, or owes a fiduciary or similar duty to the respective Obligor, in connection with such transactions or the process leading thereto.

 

  23.21

USA Patriot Act Notice

Each Facility Lender that is subject to the requirements of the USA Patriot Act, each Facility Agent (for itself and not on behalf of any Facility Lender) and the Intercreditor Agent (for itself and not on behalf of any Facility Lender) hereby notifies each Obligor that pursuant to the requirements of the USA Patriot Act, it is required to obtain, verify and record information that identifies each Obligor, which information includes the name, taxpayer identification number and business address of each Obligor and other information that shall allow such Facility Lender, Facility Agent or the Intercreditor Agent, as applicable, to identify each Obligor in accordance with the USA Patriot Act.

 

  23.22

Limited Recourse

Subject to clause (b) below, each Secured Party that is a party hereto acknowledges and agrees that the obligations of the Obligors and the Pledgor under this Agreement and the other Finance Documents, including with respect to the payment of the principal of or premium or penalty, if any, or interest on any Senior Debt Obligations, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, are obligations solely of the Obligors and the Pledgor (as applicable) and shall be satisfied solely from the security and assets of the Obligors and the Pledgor and shall not constitute a debt or obligation of Affiliates of Borrower (other than the other Obligor or the Pledgor), nor of any past, present or future shareholders, partners, members, directors, officers, employees, agents, attorneys or representatives of the Obligors and their Affiliates (collectively (but excluding the Obligors and the Pledgor), the “Non-Recourse Parties”).

 

  (a)

Each Secured Party that is a party hereto acknowledges and agrees that, subject to clause (b) below, the Non-Recourse Parties shall not be liable for any amount payable under this Agreement or any other Finance Document, and no Secured Party shall seek a money judgment or

 

-146-

Calcasieu Pass - Common Terms Agreement


  deficiency or personal judgment against any Non-Recourse Party for payment or performance of any obligation of the Obligors under this Agreement or the other Finance Documents.

 

  (b)

The acknowledgments, agreements and waivers set out in this Section 23.22 (Limited Recourse) shall be enforceable by any Non-Recourse Party and are a material inducement for the execution of this Agreement and the other Finance Documents by the Obligors; provided, however, that:

 

  (i)

the foregoing provisions of this Section 23.22 (Limited Recourse) shall not constitute a waiver, release or discharge of either Obligor or the Pledgor for any of the Indebtedness or Senior Debt Obligations of either Obligor or the Pledgor under, or any terms, covenants, conditions or provisions of, this Agreement or any other Finance Document to which any of the foregoing are party, and the same shall continue until fully and paid, discharged, observed or performed;

 

  (ii)

the foregoing provisions of this Section 23.22 (Limited Recourse) shall not limit or restrict the right of any Secured Party to name Borrower, the Guarantor, the Pledgor or any other Person as defendant in any action or suit for a judicial foreclosure or for the exercise of any other remedy under or with respect to this Agreement, any of the Security Documents or any other Finance Document to which such Person is a party, or for injunction or specific performance, so long as no judgment in the nature of a deficiency judgment shall be enforced against any Non-Recourse Party out of any property other than the property of Borrower, the Guarantor, the Pledgor, or the Collateral;

 

  (iii)

the foregoing provisions of this Section 23.22 (Limited Recourse) shall not in any way limit, reduce, restrict or otherwise affect any right, power, privilege or remedy of the Secured Parties (or any permitted assignee or beneficiary thereof or successor thereto) with respect to, and each and every Person (including each and every Non-Recourse Party) shall remain fully liable to the extent that such Person would otherwise be liable for its own actions with respect to, any fraud, bad faith, gross negligence or willful misrepresentation, or willful misappropriation of revenues or any other earnings, rents, issues, profits or proceeds from or of Borrower, the Guarantor, the Pledgor, the Project Facilities or the Collateral that should or would have been paid as provided in the Finance Documents or paid or delivered to the Collateral Agent (or any assignee or beneficiary thereof or successor thereto) for any payment required under this Agreement or any other Finance Document; and

 

-147-

Calcasieu Pass - Common Terms Agreement


  (iv)

nothing contained herein shall limit the liability of: (x) any Person who is a party to any Finance Document, Material Project Agreement or Security Document or (y) any Person rendering a legal opinion pursuant to Article 4 (Conditions Precedent) of this Agreement or otherwise, in each case under this clause (iv) relating solely to such liability of such Person as may arise under such referenced agreement, instrument or opinion.

The limitations on recourse set forth in this Section 23.22 (Limited Recourse) shall survive the Discharge Date.

 

  23.23

Entire Agreement

This Agreement (including Schedules), the Security Documents and the other Finance Documents (together with any other agreements or documents referred to or incorporated by reference therein) constitute the entire agreement and understanding, and supersede all prior agreements and understandings (both written and oral), between or among any of the Parties hereto relating to the transactions contemplated hereby or thereby other than any such agreements and undertakings contained in any commitment letter or fee letter related to the Loans stated expressly to survive the execution and delivery of this Agreement, among the Borrower, on the one hand, and the Facility Lenders, on the other hand.

 

-148-

Calcasieu Pass - Common Terms Agreement


IN WITNESS WHEREOF, the parties have caused this Agreement to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,
as the Borrower
By:  

/s/ D. Michael Eberhardt

Name:   D. Michael Eberhardt
Title:   Chief Financial Officer

 

TRANSCAMERON PIPELINE, LLC,
as the Guarantor
By:  

/s/ D. Michael Eberhardt

Name:   D. Michael Eberhardt
Title:   Chief Financial Officer

 

 

[Signature Page to Common Terms Agreement]


MIZUHO BANK, LTD.,
as the lntercreditor Agent
By:  

/s/ Brian Caldwell

Name:   Brian Caldwell
Title:   Managing Director

 

 

 

[Signature Page to Common Terms Agreement]


NATIXIS, NEW YORK BRANCH,
as the Credit Facility Agent
By:  

/s/ Urs B. Fischer

Name:   Urs B. Fischer
Title:   Executive Director

 

By:  

/s/ Hana Beckles

Name:  

Hana Beckles

Title:  

Director

 

 

 

[Signature Page to Common Terms Agreement]


SCHEDULE A

COMMON DEFINITIONS AND RULES OF INTERPRETATION

 

1.1

Amendments

No amendment to any definition or rule of interpretation in this schedule shall be effective for purposes of any individual Finance Document unless such amendment has complied with the requirements for amendments to that Finance Document.

 

1.2

Interpretation

In this Agreement and in the Appendices, Exhibits and Schedules hereto, except to the extent that the context otherwise requires:

 

  (a)

the Table of Contents and headings are for convenience only and shall not affect the interpretation of this Agreement;

 

  (b)

unless otherwise specified, references to Articles, Sections, clauses, Appendices, Exhibits and Schedules are references to Articles, Sections and clauses of, and Appendices, Exhibits and Schedules to, this Agreement;

 

  (c)

references to any document or agreement shall be deemed to include references to such document or agreement as amended (however fundamentally), supplemented or replaced from time to time in accordance with its terms and (where applicable) subject to compliance with the requirements set forth herein and therein; provided that with respect to any references to the Equator Principles, such references shall be deemed to refer to such documents in effect as of the Closing Date, without regard to any amendments, supplements or replacements thereof after such date;

 

  (d)

references to any party to this Agreement or any other document or agreement shall include its successors and permitted transferees and assigns;

 

  (e)

an “authorization” includes an authorization, consent, approval, resolution, license, exemption, filing, registration and notarization;

 

  (f)

a “month” is a reference to a period starting on one day in a calendar month and ending on the numerically corresponding day in the next calendar month, except that, if there is no numerically corresponding day in the month in which that period ends, that period shall end on the last day in that month;

 

  (g)

words importing the plural include the singular and vice versa;

 

-149-

Calcasieu Pass - Common Terms Agreement


  (h)

whenever the context may require, any pronoun shall include the corresponding masculine, feminine and neuter forms;

 

  (i)

the words “include”, “includes” and “including” shall be deemed to be followed by the phrase “without limitation”;

 

  (j)

the word “will” shall be construed to have the same meaning and effect as the word “shall”;

 

  (k)

law” shall be construed as any law (including common or customary law), statute, constitution, decree, judgment, treaty, regulation, directive, by-law, order, ordinance or any other legislative measure of any government, supranational, local government, statutory or regulatory body or court, in each case having the force of law;

 

  (l)

unless as otherwise provided, any reference to assignment of a person’s rights and/or obligations shall be construed to refer to assignment, transfer or novation of those rights and/or obligations;

 

  (m)

any reference to the actions or omissions of agents, representatives or authorized persons shall refer only to actions or omissions taken in connection with the agency, representation or authorization (so that, for example, an action or omission of a contractor for any Obligor shall be the action of an agent, representative or authorized person of the Obligors only if taken in connection with the performance of its work under its contract with any Obligor involving work related to the Development, and shall not be the action or omission of an agent, representative or authorized person of the Obligors if taken under another contract with persons other than the Obligors involving work unrelated to the Development);

 

  (n)

the omission of the word “any” or the phrase “if any” with respect to anything shall not imply that the thing exists or is required, notwithstanding the inclusion of such word or phrase (for clarity) in other provisions;

 

  (o)

any reference to an action being taken “pursuant to” an agreement or document, or any specified provision thereof, shall be construed to mean “pursuant to and in compliance with” the requirements of such agreement, document or provision;

 

  (p)

in some instances, a word or reference that, pursuant to these rules of interpretation, is not necessary (for example, inclusion of both the singular and plural), may be included for emphasis or clarity, and any such usage shall not give rise to any negative implication in relation to any other usage, which other usage shall nonetheless be interpreted strictly in accordance with the rules of interpretation set forth herein;

 

-150-

Calcasieu Pass - Common Terms Agreement


  (q)

unless the contrary indication appears, a reference to a time of day is a reference to the time of day in New York, New York, United States; and

 

  (r)

the words “hereof”, “herein”, “hereto” and “hereunder” and words of similar import when used in this Agreement shall refer to this Agreement as a whole and not to any particular provision of this Agreement.

 

1.3

Definitions

Abandonment” means any of the following shall have occurred:

 

  (a)

the abandonment, suspension or cessation of all or substantially all of the activities related to the Development or the abandonment, suspension or cessation of operations of the Project Facilities, in each case, for a period in excess of 60 consecutive days (other than as a result of force majeure so long as the Borrower is diligently attempting to restart the Development or the Project Facilities); provided that if this is not accompanied by a formal, public announcement by the Borrower of its intentions as set forth in clause (b) below, such abandonment, suspension or cessation shall not have occurred unless, within 45 days following notice to the Borrower from the Collateral Agent (who may be instructed by any Senior Creditor Group to deliver such notice) requesting the Borrower to deliver a certificate to the effect that it will resume construction or operation as soon as is commercially reasonable, the Borrower has not delivered such certificate or resumed such activities or, if such certificate is delivered, the Borrower has nevertheless not resumed such activities within 90 days following receipt of the notice from the Collateral Agent;

 

  (b)

a formal, public announcement by the Borrower of a decision to abandon, cease or indefinitely defer or suspend the Development for any reason; or

 

  (c)

the Borrower shall make any filing with FERC giving notice of the intent or requesting authority to abandon the Development for any reason.

Acceptable Bank” means a bank whose long-term unsecured and unguaranteed debt is rated at least A- (or the equivalent rating) from S&P or Fitch or at least A-3 (or the equivalent rating) from Moody’s, and, in any case, with a combined capital surplus of at least $1 billion.

Acceptable Debt Service Reserve LC” means an irrevocable, standby letter of credit issued by an Acceptable Bank for the benefit of the Collateral Agent that includes the following material terms:

 

  (a)

an expiration date no earlier than 364 days following its issuance date;

 

  (b)

allows the Collateral Agent to make a drawdown of up to the stated amount in each of the circumstances described in Section 4.9(d) (Acceptable Debt Service Reserve LC) of the Common Security and Account Agreement; and

 

-151-

Calcasieu Pass - Common Terms Agreement


  (c)

the reimbursement and other payment obligations with respect to such letter of credit are not for the account of any Obligor.

Acceptable Lender” means any Sponsor or its Affiliate or a bank, financial institution, multilateral agency, development financial institution, trust, Approved Fund, insurance company, investment or mutual fund or other entity that is an “accredited investor” (as defined in Regulation D under the Securities Act) or any Senior Creditor (other than the Senior Noteholders that are not otherwise Acceptable Lenders) or any Affiliate of a Facility Lender or any other entity or Person, that in each case is regularly engaged in or established for the purpose of making, purchasing or investing in loans, securities or other financial assets (including credit derivatives) in the ordinary course of business; provided that, in the case of trusts and funds that are not Approved Funds, such entity shall be experienced in the financing of energy and natural resource projects; provided, further, that no Disqualified Institution shall be an “Acceptable Lender” hereunder.

Access Information” has the meaning given in Section 23.8(f)(ii) (Notices) of the Common Terms Agreement.

Access License Agreements” mean:

 

  (a)

Access License Agreement (2.65 Acres), dated as of March 20, 2019, between CP Marine Offloading, LLC, as grantor, and the Borrower, as grantee (Parcel K);

 

  (b)

Access License Agreement (5.4 Acres), dated as of March 20, 2019, between CP Marine Offloading, LLC, as grantor, and the Borrower, as grantee (Parcel L);

 

  (c)

Access License Agreement (7.2 Acres), dated as of March 20, 2019, between CP Marine Offloading, LLC, as grantor, and the Borrower, as grantee (Parcel H);

 

  (d)

Access License Agreement (6.0 Acres), dated as of March 20, 2019, between CP Marine Offloading, LLC, as grantor, and the Borrower, as grantee (Parcel F-1);

 

  (e)

Access License Agreement (8.65 Acres), dated as of March 20, 2019, between CP Marine Offloading, LLC, as grantor, and the Borrower, as grantee (Parcel I);

 

-152-

Calcasieu Pass - Common Terms Agreement


  (f)

Access License Agreement (10.3 Acres), dated as of March 20, 2019, between CP Marine Offloading, LLC, as grantor, and the Borrower, as grantee (Parcel J);

 

  (g)

Access License Agreement (351 Acres), dated as of March 20, 2019, between CP Marine Offloading, LLC, as grantor, and the Borrower, as grantee (Parcels D, E, F-2);

 

  (h)

Access License Agreement (East Dredge-001.00), dated as of April 3, 2019, between CP Marine Offloading, LLC, as grantor, and the Borrower, as grantee (Dredge Servitude (McMahon)); and

 

  (i)

Access License Agreement (East Dredge-002.00), dated as of April 3, 2019, between CP Marine Offloading, LLC, as grantor, and the Borrower, as grantee (Dredge Servitude (Hoyerman)).

Accession Agreement” means any accession agreement contemplated under the Finance Documents, the form of which is included in either Schedule D (Forms of Accession Agreements) to the Common Security and Account Agreement or Schedule P – 1 (Replacement Facility Agent Accession Agreement) and Schedule P – 2 (New Facility Agent Accession Agreement (Additional Senior Debt)) to the Common Terms Agreement.

Account Bank” means, initially, Mizuho Bank, Ltd. acting in its capacity as such (with any replacement to the initial Account Bank having a then-current credit rating at appointment by S&P at least equivalent to A+ or by Moody’s at least equivalent to A1 and being subject to receipt of consent in accordance with Section 9.9(b) (Resignation, Removal and Replacement of Account Bank) of the Common Security and Account Agreement).

Account Bank Fee Letter” means the fee letter entered into between the Company and the Account Bank in respect of the fees payable to the Account Bank in respect of its services to be performed as more fully described in the Common Security and Account Agreement and the other Security Documents.

Accounts” has the meaning given in Section 4.3(a) (Accounts) of the Common Security and Account Agreement.

ACQ” has the meaning given in the applicable LNG SPA.

Additional Debt Service Reserve Account(s)” means each Account established pursuant to Section 4.3(a) (Accounts) of the Common Security and Accounts Agreement.

Additional Proceeds Prepayment Account” means the account described in Section 4.3(a)(xii) (Accounts) of the Common Security and Account Agreement.

 

-153-

Calcasieu Pass - Common Terms Agreement


Additional Senior Debt” has the meaning given in Section 2.2(a)(i) (Incremental Senior Debt) of the Common Security and Account Agreement.

Administrative Services Agreements” mean the agreements between the Obligors and the Manager for their respective Project Facilities.

Advance” means a borrowing of a loan, issuance of or drawing upon a letter of credit or the issuance of debt securities pursuant to any Senior Debt Instrument.

Affiliate” of any specified Person means any other Person directly or indirectly Controlling or Controlled by or under direct or indirect common Control with such specified Person and “Affiliated” shall be construed accordingly.

Affiliated Service Counterparties” means Calcasieu Pass Operations, LLC, Venture Global Services, LLC and TransCameron Operations, LLC.

Agreement” in each case where used means only the agreement in which the term is used. For the avoidance of doubt, (a) any reference to an individual Senior Debt Instrument which is a Facility Agreement shall be deemed to include reference to the Common Terms Agreement; and (b) references to an Indenture, or to any individual Senior Debt Instrument that is an Indenture, shall be deemed not to include reference to the Common Terms Agreement.

Amortization Schedule”, with respect to a Facility Agreement, has the meaning given in such Facility Agreement.

Anti-Terrorism and Money Laundering Laws” means any of the following (a) Section 1 of Executive Order 13224 of September 24, 2001, Blocking Property and Prohibiting Transactions With Persons Who Commit, Threaten to Commit, or Support Terrorism, (b) the Terrorism Sanctions Regulations (Title 31 Part 595 of the US Code of Federal Regulations), (c) the Terrorism List Governments Sanctions Regulations (Title 31 Part 596 of the US Code of Federal Regulations), (d) the Foreign Terrorist Organizations Sanctions Regulations (Title 31 Part 597 of the US Code of Federal Regulations), (e) the USA Patriot Act of 2001 (Pub. L. No. 107-56), (f) the US Money Laundering Control Act of 1986 (i.e., Laundering of Monetary Instruments, 18 U.S.C. section 1956, and Engaging in Monetary Transactions in Property Derived from Specified Unlawful Activity, 18 U.S.C. section 1957), (g) the Bank Secrecy Act, 31 U.S.C. sections 5301 et seq., (h) the Financial Recordkeeping and Reporting of Currency and Foreign Transactions Regulations (Title 31 Chapter X of the US Code of Federal Regulations), (i) any other similar federal Government Rule having the force of law and relating to money laundering, terrorist acts or acts of war and (j) any regulations promulgated under any of the foregoing.

Applicable Anti-Corruption Laws” means the Foreign Corrupt Practices Act of 1977 and the rules and regulations thereunder and all laws, rules, and regulations of any jurisdiction applicable to the Borrower, the Borrower’s Subsidiaries or any Guarantor at the relevant time concerning or relating to bribery or corruption.

 

-154-

Calcasieu Pass - Common Terms Agreement


Approved Bank” means any commercial bank or financial institution that (i) is not an Affiliate of the Obligors, the Sponsor or the Approved Owners and (ii) has a credit rating of at least A+ by S&P and at least A1 by Moody’s, in each case, as of the Closing Date or at the time it enters into a Permitted Hedging Instrument.

Approved Fund” means any Fund administered or managed by (a) a Facility Lender, (b) an Affiliate of a Facility Lender or (c) an entity or an Affiliate of an entity that administers or manages a Facility Lender.

Approved Owner” means (a) any of Stonepeak Infrastructure Fund III LP, Stonepeak Partners LP, Stonepeak Bayou Holdings LP, Stonepeak Bayou Holdings II LP or any of their respective Affiliates and (b) any other Person that is approved by the Required Intercreditor Parties.

Authorized Investments” means any US Dollar denominated investments that are:

 

  (a)

direct obligations of, or obligations the principal and interest on that are unconditionally guaranteed by, the United States of America (or any instrumentality thereof to the extent such obligations are backed by the full faith and credit of the United States of America), in each case maturing within one year from the date of acquisition thereof;

 

  (b)

investments in marketable general obligations issued by any state of the United States of America or any political subdivision of any such state or any public instrumentality thereof in each case maturing within one year from the date of acquisition thereof and having, at such date of acquisition, a credit rating of “A” or higher from S&P or from Moody’s (or if at such time neither is issuing ratings, then a comparable rating of such other nationally recognized rating agency as shall be approved by the Collateral Agent in its reasonable judgment);

 

  (c)

commercial paper or tax exempt obligations having one of the two highest ratings obtainable from Moody’s or S&P (or if at such time neither is issuing ratings, then a comparable rating of such other nationally recognized rating agency as shall be approved by the Collateral Agent in its reasonable judgment) and, in each case, maturing within one year of acquisition thereof;

 

  (d)

investments in certificates of deposit, banker’s acceptances and time deposits maturing or putable within one year from the date of acquisition thereof issued or guaranteed or placed with, and money market deposit accounts issued or offered by, any domestic office of (i) a commercial bank organized under the laws of the United States of America or any

 

-155-

Calcasieu Pass - Common Terms Agreement


  state thereof or (ii) a licensed branch of a foreign bank organized under the laws of any member country of the Organization for Economic Co- Operation and Development, in either case, that has a combined capital and undivided surplus and undivided profits of at least $500 million;

 

  (e)

fully collateralized repurchase agreements with a term of not more than 30 days for securities described in clause (a) of this definition and entered into with a financial institution satisfying the criteria described in clause (d) of this definition; or

 

  (f)

money market funds that (i) comply with the criteria set forth in Securities and Exchange Commission Rule 2a-7 (or any successor rule) under the Investment Company Act of 1940; (ii) are rated either AAA by S&P and Aaa by Moody’s or at least 95% of the assets of which constitute Authorized Investments described in clauses (a) through (e) of this definition and/or US Dollars; and (iii) have portfolio assets of at least $500 million.

Authorized Officer” means: (a) with respect to any Person that is a corporation, the chairman, president, senior vice president, vice president, chief financial officer, chief operating officer, treasurer, assistant treasurer, attorney-in-fact, secretary or assistant secretary of such Person, (b) with respect to any Person that is a partnership, the chairman, president, senior vice president, vice president, chief financial officer, chief operating officer, treasurer, assistant treasurer, attorney-in-fact, secretary or assistant secretary of such Person or a general partner of such Person and (c) with respect to any Person that is a limited liability company, the chairman, president, senior vice president, chief financial officer, chief operating officer, vice president, treasurer, assistant treasurer, attorney-in- fact, secretary or assistant secretary, the manager, the managing member or a duly appointed officer of such Person.

Availability Period” means, (a) with respect to the Term Loans, the Term Loan Availability Period, (b) with respect to the Working Capital Loans, the Working Capital Loan Availability Period, (c) with respect to Letters of Credit, the Working Capital Availability Period and (d) with respect to any other Loans, the period commencing on the date of first disbursement of such Loans and ending on the date of the termination or cancellation of all remaining Facility Debt Commitments pursuant to the terms of the corresponding Facility Agreement.

Bail-in Action” means the exercise of any Write-Down and Conversion Powers by the applicable EEA Resolution Authority in respect of any liability of an EEA Financial Institution.

Bail-In Legislation” means, with respect to any EEA Member Country implementing Article 55 of Directive 2014/59/EU of the European Parliament and of the Council of the European Union, the implementing law for such EEA Member Country from time to time which is described in the EU Bail-In Legislation Schedule.

 

-156-

Calcasieu Pass - Common Terms Agreement


Bankruptcy” means with respect to any Person, the occurrence of any of the following events, conditions or circumstances:

 

  (a)

such Person shall file a voluntary petition in bankruptcy, or shall file any petition or answer or consent seeking any reorganization, arrangement, adjustment, composition, insolvency, liquidation, receivership, dissolution or similar relief for itself under the Bankruptcy Code or any present or future applicable federal, state or other statute or law relating to bankruptcy, insolvency, reorganization or other relief for debtors generally, or shall apply for or consent to the appointment of any trustee, receiver, conservator or liquidator of such Person or of all or any substantial part of its properties;

 

  (b)

a case or other proceeding shall be commenced against such Person in a court of competent jurisdiction without the consent or acquiescence of such Person seeking any reorganization, arrangement, adjustment, composition, insolvency, liquidation, receivership, dissolution or similar relief with respect to such Person or its debts under the Bankruptcy Code or any present or future applicable federal, state or other statute or law relating to bankruptcy, insolvency, reorganization or other relief for debtors generally, or seeking the appointment of a trustee, receiver, liquidator, custodian or other similar official of it or any substantial part of its property, and such involuntary case or other proceeding shall remain undismissed or unstayed for a period of 60 consecutive days;

 

  (c)

a court of competent jurisdiction shall enter an order, judgment or decree approving a petition with respect to such Person seeking a reorganization, arrangement, composition, readjustment, liquidation, dissolution or similar relief under the Bankruptcy Code, or any other present or future applicable federal, state or other statute or law relating to bankruptcy, insolvency, reorganization or other relief for debtors, and such Person shall consent to the entry of such order, judgment or decree or such order, judgment or decree shall remain undischarged, unvacated or unstayed for 90 days (whether or not consecutive) from the date of entry thereof, or any trustee, receiver, conservator or liquidator of such Person or of all or any substantial part of its property shall be appointed without the consent of such Person and such appointment shall remain undischarged, unvacated and unstayed for an aggregate of 90 days (whether or not consecutive);

 

  (d)

such Person shall admit in writing its inability to pay its debts as they mature or shall generally not be paying its debts as they become due;

 

  (e)

such Person shall make a general assignment for the benefit of creditors or take any other similar action for the protection or benefit of creditors; or

 

-157-

Calcasieu Pass - Common Terms Agreement


  (f)

the board of directors, board of managers or similar body, or the member(s) of such Person shall take any corporate or partnership action for the purpose of effecting any of the foregoing.

Bankruptcy Code” means the United States Bankruptcy Reform Act of 1978 and codified as 11 U.S.C. Section 11 et seq.

Bankruptcy Default” has the meaning given in Section 6.2(c) (Initiation of Security Enforcement Action Bankruptcy Default) of the Common Security and Account Agreement.

Base Case Forecast” means the base case forecast attached as Schedule R (Base Case Forecast) to the Common Terms Agreement, as may be updated from time to time in accordance with the Common Terms Agreement.

Base Case Sizing Criteria” means (a) beginning with the Project Completion Date and for each calendar year thereafter (through the underlying amortization period of the Initial Senior Debt), including any stub year, a minimum DSCR of 1.50:1 and (b) a Senior Debt/Equity Ratio of no greater than 75:25, based, in each case, on Cash Flow Available for Debt Service from the fixed component under the Initial LNG SPAs (not counting for any sale of the Supplemental Quantity) and, solely to the extent when sizing the amount of any mandatory prepayment after the Closing Date, any Qualifying LNG SPAs that are then in full force and effect and on a twenty (20) year amortization profile, and assuming no lifting of LNG and no merchant sales of LNG.

Base Committed Quantity” means eight (8) MTPA, being the aggregate ACQ under the Initial LNG SPAs; provided that (a) following the full payment of the required amount upon any LNG SPA Mandatory Prepayment, the Base Committed Quantity will be equal to the aggregate ACQ under the Qualifying LNG SPAs used to calculate the amount of Senior Debt that the Borrower is not required to repay upon an LNG SPA Prepayment Event under Section 3.4(a)(iii) (Mandatory Prepayments LNG SPA Payment Events) of the Common Terms Agreement and (b) to the extent that any other LNG SPA becomes a Qualifying LNG SPA or an existing Qualifying LNG SPA is amended to adjust the quantity of LNG contracted to be sold thereunder, the Base Committed Quantity will be equal to the aggregate ACQ under the Qualifying LNG SPAs as at such time.

Basis Swap” means a commodity derivative contract that is cash-settled based on the difference between: (a) the price of natural gas at one particular pricing point and (b) the price of natural gas at a different delivery location or pricing point.

Bcf” means billions of cubic feet.

Beneficial Ownership Certification” means a certification regarding beneficial ownership as required by the Beneficial Ownership Regulation.

 

-158-

Calcasieu Pass - Common Terms Agreement


Beneficial Ownership Regulation” 31 C.F.R. § 1010.230.

BHGE” means GE Oil & Gas, LLC.

Borrower” means Venture Global Calcasieu Pass, LLC, a limited liability company organized under the laws of the State of Delaware. The Borrower is also referred to as the “Company” under the Common Security and Account Agreement and the “Mortgagor” under the Mortgage.

BP” means BP Gas Marketing Limited.

Breakage Costs” under a Facility Agreement has the meaning given in such Facility Agreement.

Btu” means the amount of heat required to raise the temperature of one avoirdupois pound of pure water from fifty-nine degrees (59°) Fahrenheit to sixty degrees (60°) Fahrenheit at a pressure of fourteen point six nine six (14.696) pounds per square inch absolute (psia).

Business Day” means a day (other than a Saturday or Sunday) on which banks are generally authorized to be open for business:

 

  (a)

in relation to any determination of the LIBOR (as defined in the Credit Facility Agreement or in any other Finance Document) required under the Finance Documents, London; and

 

  (b)

in all other cases, The City of New York.

Business Interruption Insurance Proceeds” means all proceeds of any insurance policies required pursuant to the Schedule of Minimum Insurance or otherwise obtained with respect to the Obligors or the Project Facilities insuring the Obligors against business interruption or delayed start-up.

Cash Flow” means, with respect to any period, all funds received or, as applicable in the relevant context, projected to be received by the Obligors during such period, without duplication, including:

 

  (a)

amounts received by the Borrower under the LNG SPAs (including in respect of Supplemental Quantities sold by the Borrower as permitted under Section 8.4 (Sale of Supplemental Quantity) and in respect of quantities of LNG sold by the Borrower prior to the Commercial Operation Date as permitted under Section 8.5 (Sale of Pre-Commercial Quantities);

 

  (b)

earnings on funds held in the Secured Accounts (excluding interest and investment earnings that accrue on the amounts on deposit in any of the Senior Facilities Debt Service Reserve Account or any account established

 

-159-

Calcasieu Pass - Common Terms Agreement


  to prefund interest on any Senior Debt, if any, in any case, that are not transferred to the Revenue Account pursuant to the Common Security and Account Agreement);

 

  (c)

any amounts deposited in the Insurance/Condemnation Proceeds Account to the extent applied to the payment of Operation and Maintenance Expenses or Project Costs in accordance with Article 5 (Insurance and Condemnation Proceeds and Performance Liquidated Damages) of the Common Security and Account Agreement;

 

  (d)

all cash paid to the Obligors during such period as Business Interruption Insurance Proceeds;

 

  (e)

proceeds from the transfer, sale or disposition of assets or rights of the Obligors in the ordinary course of business in accordance with Section 12.17 (Sale of Project Property) of the Common Terms Agreement (other than as set forth in sub-clause (6) below) to the extent such proceeds have been or will be used to pay Operation and Maintenance Expenses;

 

  (f)

amounts paid to each Obligor under any Material Project Agreement;

 

  (g)

amounts received by each Obligor under Permitted Hedging Instruments other than in respect of interest rates;

 

  (h)

with respect to the calculation of the Historical DSCR for any purpose other than such calculation under Section 11 (Restricted Payments) of the Common Terms Agreement, and for any period, all cash paid to the Borrower during the applicable period from any direct or indirect owner of the Borrower by way of Equity Funding (in each case as otherwise permitted pursuant to the terms of the Finance Documents) in accordance with Section 12.25(b) (Historical DSCR); and

 

  (i)

with respect to the calculation of Fixed Projected DSCR for any purpose other than such calculation under Section 11 (Restricted Payments) of the Common Terms Agreement, and for any period, any cash projected to be on deposit in the Secured Accounts at the commencement of such period as a result of a restriction on the making of Restricted Payments applicable prior to such period (without double counting any other amounts of Cash Flow taken into account in the calculation of the Fixed Projected DSCR);

but excluding, in each case:

 

  (1)

all amounts required to be deposited in the Insurance/Condemnation Proceeds Account used to reimburse Equity Funding;

 

  (2)

all proceeds of Senior Debt that are used to reimburse Drawstop Equity Contributions;

 

-160-

Calcasieu Pass - Common Terms Agreement


  (3)

proceeds of the final Advance on the Project Completion Date;

 

  (4)

the proceeds of the Project Completion Date Distribution;

 

  (5)

proceeds of third-party liability insurance;

 

  (6)

proceeds of the sale of assets permitted by Section 12.17(c) or (l) (Sale of Project Property) of the Common Terms Agreement unless and until applied to procure a replacement for such assets;

 

  (7)

proceeds of Senior Debt and other Indebtedness (and corresponding amounts received by the Obligors pursuant to any guarantees) permitted by Section 12.14 (Limitation on Indebtedness) of the Common Terms Agreement other than amounts received under Permitted Hedging Instruments included under clause (g) above;

 

  (8)

except as provided in clause (h) above, Equity Funding received from the Sponsor or any direct or indirect holders of equity interests of the Borrower; and

 

  (9)

any cash deposited into the Additional Proceeds Prepayment Account.

Cash Flow Available for Debt Service” means, for each applicable measurement period, the amount equal to (a) Cash Flow for such period minus (b) Operation and Maintenance Expenses for such period; provided that Operation and Maintenance Expenses included in the calculation of Historical DSCR and Fixed Projected DSCR will exclude (i) that portion of Operation and Maintenance Expenses arising prior to the Project Completion Date that are Project Costs and (ii) Operation and Maintenance Expenses arising from and after the Project Completion Date relating to expenditure on items that were, as of the Project Completion Date, outstanding or punch list items under the Material Construction Contracts, and for which sufficient reserves are on deposit in the Completion Reserve Account.

CB&I” means CB&I LLC.

CERCLA” means the Comprehensive Environmental Response, Compensation and Liability Act (42 U.S.C. section 9604, et seq.) and rules and regulations issued thereunder.

Cessation Notice” has the meaning given in Section 15.3 (Cessation of Loan Facility Declared Default) of the Common Terms Agreement.

Change in Law” means the occurrence, after the Closing Date, of any of the following:

 

  (a)

the adoption or taking effect of any law;

 

-161-

Calcasieu Pass - Common Terms Agreement


  (b)

any change in any law or in the administration, interpretation, implementation or application thereof by any Governmental Authority; or

 

  (c)

the making or issuance of any request, rule, guideline or directive (whether or not having the force of law) by any Governmental Authority;

provided that, notwithstanding anything herein to the contrary, (x) the Dodd- Frank Wall Street Reform and Consumer Protection Act and all requests, rules, guidelines or directives thereunder or issued in connection therewith and (y) all requests, rules, guidelines or directives promulgated by the Bank for International Settlements, the Basel Committee on Banking Supervision (or any successor or similar authority) or the United States or foreign regulatory authorities, in each case pursuant to Basel III, shall in each case be deemed to be a “Change in Law”, regardless of the date enacted, adopted or issued.

Change of Control” means

 

  (a)

prior to the Project Completion Date, the Sponsor and any Approved Owners, collectively, shall cease to, directly or indirectly, maintain (i) voting or managerial control of the Borrower or the Guarantor or (ii) 100% of the economic interest in the Borrower or the Guarantor; or

 

  (b)

after the Project Completion Date, (i) the Sponsor, any Approved Owners and any Qualified Owners, collectively, shall cease to, directly or indirectly, maintain voting or managerial control of the Borrower or the Guarantor or (ii) the Sponsor, any Approved Owners and any Qualified Owners, collectively, shall cease to, directly or indirectly, maintain more than 50% of the economic interest in the Borrower or the Guarantor; or

 

  (c)

at any time, the Pledgor shall cease to directly maintain 100% of the voting and economic interests in the Borrower or the Guarantor.

Change Order” has the meaning given in the Material Construction Contract.

Closing” means the satisfaction or waiver of all the conditions precedent set forth in Section 4.1 (Conditions to Closing Date and Initial Advance) and Section 4.2 (Conditions to Each Advance) of the Common Terms Agreement, with respect to the Initial Senior Debt.

Closing Conditions Certificate” has the meaning given in Section 4.4(a)(i) (Satisfaction of Conditions) of the Common Terms Agreement.

Closing Date” means the date on which the conditions precedent set forth in Section 4.1 (Conditions to Closing Date and Initial Advance) and Section 4.2 (Conditions to Each Advance) of the Common Terms Agreement have been satisfied or waived.

 

-162-

Calcasieu Pass - Common Terms Agreement


Closing Date Equity Funding” has the meaning given in Section 4.1(z) (Equity Funding) of the Common Terms Agreement.

Closing Notice” has the meaning given in Section 4.4(a)(i) (Satisfaction of Conditions) of the Common Terms Agreement.

Code” means the Internal Revenue Code of 1986.

Collateral” means any property right or interest subject to a Security Interest.

Collateral Agency Fee Letter” means the fee letter entered into between the Borrower, the Guarantor and the Collateral Agent in respect of the fees payable to the Collateral Agent in respect of its services to be performed as more fully described in the Common Security and Account Agreement and the other Finance Documents.

Collateral Agent” means the trustee named under the Common Security and Account Agreement as collateral agent for the Secured Parties.

Collateral Parties” means the Obligors and Pledgor, and “Collateral Party” shall have a corresponding meaning.

Collateral Records” means books, records, ledger cards, files, correspondence, customer lists, supplier lists, blueprints, technical specifications, manuals, computer software and related documentation, computer printouts, tapes, disks and other electronic storage media and related data processing software and similar items that at any time evidence or contain information relating to any of the Collateral or are otherwise necessary or helpful in the collection thereof or realization thereupon.

Commercial Operation Date” has the meaning given in the applicable LNG SPA.

Commodity Exchange Act” means the Commodity Exchange Act, as amended (7 U.S.C. § 1 et seq.).

Common Collateral” means any property right or interest subject to a Security Interest granted or purported to be created by or pursuant to Section 3.2(a) (Security Interests to be Granted by the Securing Parties – Pledge of Pledged Collateral), Section 3.2(b) (Security Interests to be Granted by the Securing Parties – Security Interests – General) or Section 3.2(f) (Security Interests to be Granted by the Securing Parties – Real Property) of the Common Security and Account Agreement or pursuant to any Security Document other than (a) the Senior Facilities Debt Service Reserve Account and the funds on deposit therein and (b) any Additional Debt Service Reserve Account and the funds on deposit therein, in each case, which shall be applied in accordance with Section 7.7 (Sharing) of the Common Security and Accounts Agreement.

 

-163-

Calcasieu Pass - Common Terms Agreement


Common Security and Account Agreement” means the Common Security and Account Agreement, dated as of August 19, 2019, among the Borrower, the Guarantor, each Senior Creditor Group Representative on its own behalf and on behalf of the relevant Senior Creditor Group, the Intercreditor Agent, the Collateral Agent and the Account Bank.

Common Terms Agreement” means the Common Terms Agreement, dated as of August 19, 2019, among the Borrower, the Guarantor, the Credit Facility Agent and each other Facility Agent on behalf of its respective Facility Lenders, and the Intercreditor Agent providing common representations, warranties, undertakings and events of default. For the avoidance of doubt, (i) any reference to an individual Senior Debt Instrument which is a Facility Agreement shall be deemed to include reference to the Common Terms Agreement; and (ii) references to an Indenture, or to any individual Senior Debt Instrument that is an Indenture, shall be deemed not to include reference to the Common Terms Agreement.

Company” means Venture Global Calcasieu Pass, LLC, a limited liability company organized under the laws of the State of Delaware. The Company is also referred to as the “Borrower” in certain Finance Documents, the “Mortgagor” in the Mortgage, and the “Issuer” in other Finance Documents.

Completion Reserve Account” means the account described in Section 4.3(a)(xiv) (Accounts) of the Common Security and Account Agreement.

Condemnation Proceeds” means any amounts and proceeds of any kind (including instruments) payable in respect of any Event of Taking.

Confidential Information” means all information received from any Obligor, the Pledgor, the Sponsor, any Approved Owner or any of their respective Affiliates or on their behalf relating to any of such entities, their respective businesses, the Project Facilities, the Material Project Agreements or the Development.

Connection Income Taxes” means Other Connection Taxes that are imposed on or measured by net income (however denominated) or that are franchise Taxes or branch profits Taxes.

Constitutional Documents” means certificates of formation, limited liability company agreements, partnership agreements, certificates of incorporation, bylaws or any similar entity organizational or constitutive document.

Construction Account” is the account described in Section 4.3(a)(iv) (Accounts) of the Common Security and Account Agreement.

Construction Budget and Schedule” means (a) the budget delivered pursuant to Section 4.1(g)(i) (Conditions to Closing Date and Initial Advance – Project Development) of the Common Terms Agreement (which shall be substantially in the form of budget attached as Schedule D-1 (Construction Budget and Schedule

 

-164-

Calcasieu Pass - Common Terms Agreement


Construction Budget) to the Common Terms Agreement) and (b) the schedule delivered pursuant to Section 4.1(g)(i) (Conditions to Closing Date and Initial Advance – Project Development) of the Common Terms Agreement (which shall be substantially in the form of schedule attached as Schedule D-2 (Construction Budget and Schedule – Construction Schedule).

Construction Contractors” means the EPC Contractor, the Pipeline Contractor, BHGE, UOP, Weeks Marine and CB&I.

Consultants” has the meaning given in Section 13.1 (Appointment of Consultants) of the Common Terms Agreement.

Contingency Reserve Account” is the account described in Section 4.3(a)(ix) (Accounts) of the Common Security and Account Agreement.

Contingency Reserve Amount” means an amount equal to (a) $[***], as reduced from time to time by (b) any increase in the aggregate Project Costs of the Project Facilities as compared to the Project Costs contemplated by the Construction Budget and Schedule as evidenced by a change order entered into pursuant to Section 9.1 (Change Orders); provided that such amount shall not be less than zero.

Contingency Reserve Term Loan Commitment” has the meaning provided in the Credit Facility Agreement.

Continuing”(including, with its corresponding meaning, the terms “Continuance” and “Continuation”) means:

 

  (a)

with respect to any Loan Facility Declared Default, Indenture Declared Default or other comparable event of default or termination event under any other Senior Debt Instrument or Permitted Hedging Instrument, that such event of default or termination event has occurred without the need for declaration, or been declared by required Senior Creditor action, in each case in conformity with the requirements of the Common Terms Agreement or such other Senior Debt Instrument or Permitted Hedging Instrument, as the case may be, and no Cessation Notice or similar notice shall have been given with respect thereto;

 

  (b)

with respect to any Unmatured Loan Facility Event of Default, Unmatured Indenture Event of Default or other unmatured default or termination event under any other Senior Debt Instrument or Permitted Hedging Instrument, that such unmatured default or termination event has occurred and has not been waived or cured; and

 

  (c)

with respect to any Loan Facility Event of Default, Indenture Event of Default or other event of default or termination event under any other Senior Debt Instrument or Permitted Hedging Instrument, that such event of default or termination event has occurred and has not been declared, waived or cured.

 

-165-

Calcasieu Pass - Common Terms Agreement


Contract Sales Price” has the meaning given in the applicable LNG SPA.

Control” of a Person means the power to direct the management and policies of that Person, directly or indirectly, whether through the ownership of voting securities, by operation of law, by contract (including pursuant to a partnership or similar agreement) or otherwise; and the terms “Controlling” and “Controlled” have corresponding meanings to the foregoing.

Control Agreements” means (i) the Deposit Account Control Agreement to be entered into by and among the Borrower, the Collateral Agent and Bank of America, N.A., with respect to the account labeled “Borrower Local Account (Bank of America)” on Schedule H to the Common Security and Account Agreement (Details of Initial Accounts) and (ii) the Deposit Account Control Agreement to be entered into by and among the Guarantor, the Collateral Agent and Bank of America, N.A., with respect to the account labeled “Guarantor Local Account (Bank of America)” on Schedule H to the Common Security and Account Agreement (Details of Initial Accounts).

Controlling Claimholders” means Senior Creditor Group Representatives representing a Majority in Interest of the Senior Creditors.

Copyright Licenses” means any and all agreements, licenses and covenants providing for the granting of any right in or to any Copyright or otherwise providing for a covenant not to sue for infringement or other violation of any Copyright (whether an Obligor is licensee or licensor thereunder) including each agreement required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Copyright Licenses” (as such schedule may be amended or supplemented from time to time).

Copyrights” means all United States, and foreign copyrights (whether or not the underlying works of authorship have been published), including copyrights in software and all rights in and to databases, all designs (including but not limited to industrial designs, Protected Designs within the meaning of 17 U.S.C. 1301 et. seq. and Community designs), and all Mask Works (as defined under 17 U.S.C. 901 of the US Copyright Act), whether registered or unregistered, as well as all moral rights, reversionary interests, and termination rights, and, with respect to any and all of the foregoing:

 

  (a)

all registrations and applications therefor including the registrations and applications required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Copyrights” (as such schedule may be amended or supplemented from time to time);

 

-166-

Calcasieu Pass - Common Terms Agreement


  (b)

all extensions, renewals and restorations thereof;

 

  (c)

all rights to sue or otherwise recover for any past, present and future infringement or other violation thereof;

 

  (d)

all proceeds of the foregoing, including license fees, royalties, income, payments, claims, damages and proceeds of suit now or hereafter due and/or payable with respect thereto; and

 

  (e)

all other rights of any kind accruing thereunder or pertaining thereto throughout the world.

CP Satisfaction Date” has the meaning given in the applicable LNG SPA.

Credit Agreement Reserve Account” is the account described in Section 4.3(a)(vii) (Accounts) of the Common Security and Account Agreement.

Credit Facility Agency Fee Letter” means the fee letter entered into between the Borrower, the Guarantor and the Credit Facility Agent in respect of the fees payable to the Credit Facility Agent in respect of its services to be performed as more fully described in the Credit Facility Agreement and the other Finance Documents.

Credit Facility Agent” means the facility agent under the Credit Facility Agreement.

Credit Facility Agreement” is the Credit Facility Agreement, dated as of the Closing Date, by and among the Borrower, the Guarantor, the Credit Facility Lender Parties party thereto from time to time, the Credit Facility Agent and, solely for purposes of Section 3.06 thereof, the Collateral Agent.

Credit Facility Lender Parties” means the Credit Facility Lenders and the Issuing Banks under the Credit Facility Agreement.

Credit Facility Lenders” means the “Lenders” under the Credit Facility Agreement.

Credit Facility Secured Parties” has the meaning given in Exhibit A (Definitions) to the Credit Facility Agreement.

CTA Payment Date” means (i) each Quarterly Payment Date, (ii) the date for payment of Senior Debt Obligations (including payment dates for the payment of interest) under or pursuant to any Facility Agreement or Permitted Hedging Instrument, including the Common Terms Agreement and (iii) the scheduled Final Maturity Date under each Facility Agreement.

 

-167-

Calcasieu Pass - Common Terms Agreement


Date Certain” means March 31, 2023; provided that if, on or prior to March 31, 2023, the Borrower certifies to the Intercreditor Agent (and the Independent Engineer reasonably concurs with such certification in writing) that (i) the only remaining condition to the Project Completion Date as of the date of delivery of such certification, other than conditions that can only be satisfied on the Project Completion Date, is the condition specified in Section 14.1(c)(iii) (Conditions to Occurrence of the Project Completion Date – Physical Completion Certificate) and (ii) the Lenders’ Reliability Test has commenced in accordance with the procedures specified in Section 12.11 (Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages) and is reasonably expected to be completed on or prior to June 30, 2023, then for all purposes under this Agreement the “Date Certain” means June 30, 2023.

Debt Domain Website” has the meaning given in Section 12.7(b) (Notices) of the Common Security and Account Agreement.

Debt Service” means, for any period, the sum computed without duplication, of the following: (a) all amounts payable by the Borrower in respect of scheduled principal of indebtedness during such period in respect of Senior Debt Obligations, plus (b) interest on Senior Debt Obligations (taking into account Permitted Hedging Instruments) scheduled to become due and payable (or for purposes of the Historical DSCR or Fixed Projected DSCR, accrued or paid) during such period, plus (c) all other commitment fees, agency fees, trustee fees or other administrative fees (other than upfront fees, arranging fees, underwriting fees or similar fees) payable in connection with the Senior Debt Obligations.

Debt Service Reserve Account” means the Senior Facilities Debt Service Reserve Account and each Additional Debt Service Reserve Account.

Decision” means any notice, consent, decision, approval, instruction, judgment, direction, objection or Modification.

Declared Event of Default” means an Event of Default that has been declared or is otherwise deemed to have been declared by a Senior Creditor Group Representative under its Senior Debt Instrument (acting on behalf of the Senior Creditors under, and in accordance with, such Senior Debt Instrument) or otherwise is deemed to have been declared in accordance with the terms of the relevant Senior Debt Instrument.

Default Rate” means a rate per annum equal to the rate that would otherwise be applicable plus 2%, or if there is no applicable interest rate, a rate per annum equal to the highest interest rate applicable to any then-outstanding Senior Debt plus 2%.

Defaulting Lender”, with respect to a Facility Agreement, has the meaning given in such Facility Agreement.

 

-168-

Calcasieu Pass - Common Terms Agreement


Delay Liquidated Damages” means any liquidated damages that are required to be paid to an Obligor under any Material Construction Contract by any Construction Contractor for or on account of any delay in the delivery of equipment and materials, completion of construction activities or in the completion of one or more Performance Tests.

Development” means the financing, development, engineering, acquisition, ownership, occupation, construction, equipping, testing, commissioning, completing, insurance, repair, operation, maintenance and use of the Project Facilities and the purchase, transportation and sale of Gas and the production, storage and sale of LNG, the export of LNG from the Project Facilities, the transportation of Gas to the Project Facilities by an Obligor or third parties, and the sale of other services or other products or by-products of the Project Facilities and all activities incidental thereto, in each case in accordance with the Transaction Documents. “Develop” and “Developed” shall have corresponding meanings.

Development Expenditures” means, for any period, the aggregate amount of all expenditures of the Obligors payable during such period that, in accordance with GAAP, are or should be included in “purchase of property, plant and equipment” or similar items reflected in the consolidated statement of cash flows of the Obligors.

DIP Financing” has the meaning given in Section 10.5(b) (Certain Agreements with Respect to Bankruptcy) of the Common Security and Account Agreement.

DIP Financing Liens” has the meaning given in Section 10.5(b)(ii) (Certain Agreements with Respect to Bankruptcy) of the Common Security and Account Agreement.

DIP Lenders” has the meaning given in Section 10.5(b) (Certain Agreements with Respect to Bankruptcy) of the Common Security and Account Agreement.

Direct Agreements” means:

 

  (a)

Consent to Collateral Assignment, dated as of August 19, 2019, by and among Shell, the Borrower and the Collateral Agent (or its sub-agent);

 

  (b)

Consent to Collateral Assignment, dated as of August 19, 2019, by and among Shell Oil Company, the Borrower and the Collateral Agent (or its sub-agent);

 

  (c)

Consent to Collateral Assignment, dated as of August 19, 2019, by and among Edison, the Borrower and the Collateral Agent;

 

  (d)

Direct Agreement, dated as of August 19, 2019, by and among Galp, the Borrower and the Collateral Agent;

 

-169-

Calcasieu Pass - Common Terms Agreement


  (e)

Direct Agreement, dated as of August 19, 2019, by and among Galp Energia, SGPS, S.A., the Borrower and the Collateral Agent;

 

  (f)

Consent to Assignment, dated as of August 19, 2019, by and among BP, the Borrower and the Collateral Agent;

 

  (g)

Notice and Consent to Assignment, dated as of August 19, 2019, by and among BP International Limited, the Borrower and the Collateral Agent;

 

  (h)

Consent to Collateral Assignment, dated as of August 19, 2019, by and among Repsol, the Borrower and the Collateral Agent;

 

  (i)

Consent to Collateral Assignment, dated as of August 19, 2019, by and among Repsol Exploracion, S.A., the Borrower and the Collateral Agent;

 

  (j)

Consent to Collateral Assignment, dated as of August 19, 2019, by and among PGNIG, the Borrower and the Collateral Agent;

 

  (k)

Consent and Agreement, dated as of August 19, 2019, by and among the EPC Contractor, the Borrower and the Collateral Agent;

 

  (l)

Consent and Agreement, dated as of August 19, 2019, by and among Kiewit Energy Group Inc., the Borrower and the Collateral Agent;

 

  (m)

Consent to Assignment and Agreement, dated as of August 19, 2019, by and among BHGE, the Borrower and the Collateral Agent;

 

  (n)

Consent to Assignment and Agreement, dated as of August 19, 2019, by and among General Electric Company, the Borrower and the Collateral Agent;

 

  (o)

Consent and Agreement, dated as of August 19, 2019, by and among Weeks Marine, the Borrower and the Collateral Agent;

 

  (p)

Consent and Agreement, dated as of August 19, 2019, by and among CB&I, McDermott International, Inc., the Borrower and the Collateral Agent;

 

  (q)

Consent to Assignment and Agreement, dated as of August 19, 2019, by and among UOP, the Borrower and the Collateral Agent;

 

  (r)

Consent to Assignment and Agreement, dated as of August 19, 2019, by and among Honeywell International Inc., the Borrower and the Collateral Agent;

 

  (s)

Direct Agreement, dated as of August 19, 2019, by and among Calcasieu Pass Operations, LLC, the Borrower and the Collateral Agent;

 

-170-

Calcasieu Pass - Common Terms Agreement


  (t)

Direct Agreement, dated as of August 19, 2019, by and among TransCameron Operations, LLC, the Guarantor and the Collateral Agent;

 

  (u)

Direct Agreement, dated as of August 19, 2019, by and among Venture Global Services, LLC, the Borrower and the Collateral Agent;

 

  (v)

Direct Agreement, dated as of August 19, 2019, by and among Venture Global Services, LLC, the Guarantor and the Collateral Agent;

 

  (w)

Consent and Agreement, dated as of August 19, 2019, by and among the Pipeline Contractor, the Guarantor, the Borrower and the Collateral Agent;

 

  (x)

Consent to Assignment, dated as of August 19, 2019, by and among Texas Eastern Transmission, LP, the Borrower and the Collateral Agent;

 

  (y)

Consent and Agreement, dated as of August 19, 2019, by and among ANR Pipeline Company, the Borrower and the Collateral Agent;

 

  (z)

Consent and Agreement, dated as of August 19, 2019, by and among Indigo Minerals LLC, the Borrower and the Collateral Agent;

 

  (aa)

Consent and Agreement, dated as of August 19, 2019, by and among Indigo Natural Resources LLC, the Borrower and the Collateral Agent;

 

  (bb)

Consent and Agreement, dated as of August 19, 2019, by and among EnLink Midstream Operating, LP, Bridgeline Holdings, L.P., Sabine Pipe Line LLC, the Borrower and the Collateral Agent;

 

  (cc)

Direct Agreement, dated as of August 19, 2019, by and among Venture Global Commodities, LLC, the Borrower and the Collateral Agent; and

 

  (dd)

the agreements described in Section 3.4 (Direct Agreements) of the Common Security and Account Agreement.

Disbursement Account” means the Loan Facility Disbursement Accounts and Senior Note Disbursement Accounts required to be established pursuant to Section 4.3(a)(i)-(ii) (Accounts) of the Common Security and Account Agreement.

Disbursement Endorsement” means endorsement(s) to the Title Policy (dated not earlier than two Business Days prior to the date of the requested Advance, as applicable) substantially in the form of the ALTA 33-06 Endorsement attached to as Schedule W (Form of Disbursement Endorsement) to the Common Terms Agreement (which has been paired with the ALTA 32-06 Endorsement attached to the Title Policy).

 

-171-

Calcasieu Pass - Common Terms Agreement


Disbursement Request” means a drawdown notice or request for issuance of letter(s) of credit, as applicable, substantially in the form set forth in Schedule B-1 (Disbursement Request Form (Term Loans)), Schedule B-2 (Disbursement Request Form (Working Capital Loans)) or Schedule B-3 (Issuance Request Form (Letters of Credit)) to the Common Terms Agreement (or equivalent under another Senior Debt Instrument), given by the Borrower requesting an Advance with respect to a Loan in accordance with the terms of Section 2.3 (Disbursement Procedures) of the Common Terms Agreement and/or the applicable Facility Agreement or a request for issuance of letter(s) of credit in accordance with the terms of the applicable Facility Agreement.

Discharge Date” means:

 

  (a)

with respect to the Senior Debt Obligations under a Senior Debt Instrument, the date on which such Senior Debt Obligations thereunder shall have been unconditionally paid or discharged in full in US Dollars (other than Senior Debt Obligations thereunder that by their terms survive and with respect to which no claim has been made by the applicable Senior Creditor), the Senior Debt Commitments thereunder shall have been terminated, expired or been reduced to zero and all letters of credit thereunder (if any) shall have been terminated or collateralized in accordance with the provisions of such Senior Debt Instrument;

 

  (b)

with respect to the Senior Debt Obligations under a Permitted Senior Debt Hedging Instrument, the date on which such Senior Debt Obligations thereunder shall have been unconditionally paid or discharged in full in US Dollars (other than Senior Debt Obligations thereunder that by their terms survive and with respect to which no claim has been made by the applicable Senior Creditor) and all transactions under such Permitted Senior Debt Hedging Instrument shall have terminated or expired; and

 

  (c)

with respect to all Senior Debt Obligations, collectively, the date on which each of the above shall have occurred with respect to each then-existing Senior Debt Instrument and Permitted Senior Debt Hedging Instrument and any other Senior Debt Obligations owing to the Intercreditor Agent, Facility Agents, Collateral Agent or other Secured Parties shall have been unconditionally paid or discharged in full in US Dollars (other than Senior Debt Obligations that by their terms survive and with respect to which no claim has been made by the applicable Secured Party).

Disqualified Institution” means (a) any Person set forth by the Borrower on Schedule Y (Disqualified Institutions) of the Common Terms Agreement as of the Closing Date, as updated from time to time by the Borrower by three (3) Business Days’ prior written notice to the Intercreditor Agent and each Facility Agent to add any competitor of any Obligor or (b) any clearly identifiable (solely on the basis of its name or as identified by the Borrower to the Intercreditor Agent) Affiliate of the entities described in clause (a), excluding any bona fide debt fund affiliate of such Person that is primarily engaged in, or advises funds or other investment vehicles that are engaged in, making, purchasing, holding, or

 

-172-

Calcasieu Pass - Common Terms Agreement


otherwise investing in commercial loans, bonds, and similar extensions of credit or securities in the ordinary course of its business; provided that any designation as a “Disqualified Institution” shall not apply retroactively to any then current Credit Facility Lenders or any entity that has acquired an assignment or participation interest in any Term Loans or Working Capital Loans in accordance with and under the Credit Facility Agreement. The parties to this Agreement hereby acknowledge and agree that no Facility Agent shall be deemed to be in default under this Agreement or to have any duty or responsibility or to incur any liabilities, nor shall such Facility Agent have any duty, responsibility or liability to monitor or enforce assignments, participations or other actions in respect of Disqualified Institutions, or otherwise take (or omit to take) any action with respect thereto.

Distribution Account” is the account described in Section 4.3(a)(xv) (Accounts) of the Common Security and Account Agreement.

Documentation Bank” has the meaning set forth in the Credit Facility Agreement.

Documentation Bank Fee Letters” means (i) the fee letter entered into between the Borrower, the Guarantor and Natixis, New York ranch in respect of the fees payable to Natixis, New York Branch and (ii) the fee letter entered into between the Borrower, the Guarantor and Sumitomo Mitsui Banking Corporation, in each case, in respect of its services to be performed as Documentation Bank (as more fully described in the Credit Facility Agreement and the other Finance Documents).

DOE” means the US Department of Energy.

DOT” means the US Department of Transportation.

Drawstop Equity Contributions” means contributions of cash equity made to Borrower during any period in which Borrower is unable to satisfy the conditions set forth in Section 4.2 (Conditions to Each Advance) of this Agreement, which contributions shall not be required to be deposited into the Construction Account in accordance with the Common Security and Account Agreement.

DSCR” means either Historical DSCR or Fixed Projected DSCR.

Edison” means Edison S.p.A.

EEA Financial Institution” means (a) any credit institution or investment firm established in any EEA Member Country which is subject to the supervision of an EEA Resolution Authority, (b) any entity established in an EEA Member Country which is a parent of an institution described in clause (a) of this definition, or (c) any financial institution established in an EEA Member Country which is a subsidiary of an institution described in clauses (a) or (b) of this definition and is subject to consolidated supervision with its parent.

 

-173-

Calcasieu Pass - Common Terms Agreement


EEA Member Country” means any of the member states of the European Union, Iceland, Liechtenstein, and Norway.

EEA Resolution Authority” means any public administrative authority or any Person entrusted with public administrative authority of any EEA Member Country (including any delegee) having responsibility for the resolution of any EEA Financial Institution.

Enforcement Action” has the meaning given in Section 16.1(a) (Facility Lender Remedies for Loan Facility Declared Events of Default Enforcement Action) of the Common Terms Agreement.

Enforcement Proceeds Account” has the meaning given in Section 6.7(a) (Enforcement Proceeds Account) of the Common Security and Account Agreement.

Environmental Claim” means any administrative, regulatory or judicial action, suit, judgment or other legal action (collectively, a “claim”) by any Person alleging or asserting liability for investigatory costs, response, cleanup or other remedial costs, legal costs, environmental consulting costs, governmental environmental response costs, damages to natural resources or other property, personal injuries, fines or penalties arising out of (a) the presence, Release or threatened Release into the environment, of any Hazardous Material at any location, whether or not owned by the Person against whom such claim is made, or (b) any violation of any Environmental Law. The term “Environmental Claim” will include any claim by any Person or Governmental Authority for enforcement, cleanup, removal, response, remedial action or damages pursuant to any Environmental Law, and any claim by any third party seeking damages, contribution, indemnification, cost recovery, compensation or injunctive relief under any Environmental Law.

Environmental Consultant” means Environmental Resources Management, Inc. or any independent replacement environmental consulting firm to be selected in accordance with Section 13.2 (Replacement and Fees) of the Common Terms Agreement

Environmental Laws” means all federal, state, and local statutes, laws, regulations, rules, judgments (including all tort causes of action), orders or decrees, in each case as modified and supplemented and in effect from time to time concerning the regulation, use or protection of the environment, coastal resources, protected plant and animal species, human health and safety, Hazardous Materials, including exposure to or to Releases or threatened Releases of Hazardous Materials into the environment, including ambient air, soil, surface water, groundwater, wetlands, coastal waters, land or subsurface strata, or otherwise relating to the generation, manufacture, processing, distribution, use, treatment, storage, disposal, transport or handling of Hazardous Materials.

 

-174-

Calcasieu Pass - Common Terms Agreement


EPC Change in Law” means “Change in Law” as defined in each applicable Material Construction Contract.

EPC Contract” means that certain Engineering, Procurement and Construction Agreement, dated as of November 21, 2018, by and between the Borrower and the EPC Contractor, as amended by Change Order No. 1, dated as of March 19, 2019, by and between the Borrower and the EPC Contractor, Amendment No. 1 to Engineering, Procurement and Construction Agreement, dated July 9, 2019, by and between the Borrower and the EPC Contractor and Change Order No. 2, dated July 24, 2019, by and between the Borrower and the EPC Contractor, and as supplemented by Limited Notice to Proceed, dated as of November 21, 2018, by and between the Borrower and the EPC Contractor, together with the EPC Contract Guaranty.

EPC Contractor” means Kiewit Louisiana Co.

EPC Guarantor” means the “Contractor Guarantor” as defined in the EPC Contract.

EPC Contract Guaranty” means the Guaranty, dated as of November 21, 2018, by Kiewit Energy Group Inc. in favor of the Borrower.

Equator Principles” means the principles named “Equator Principles – A financial industry benchmark for determining, assessing and managing social and environmental risk in projects” adopted by various financing institutions in the form dated June 2013, available at: http://www.equatorprinciples.com/resources/equator_principles_III.pdf.

Equity Funding” means contributions made to the Borrower in the form of (i) equity funding from a direct or indirect shareholder (including amounts funded in accordance with Section 4.1(z) (Conditions to Closing Date and Initial Advance – Equity Funding)), (ii) payment of costs in respect of the Development prior to the Closing Date, (iii) Cash Flow applied or committed to be applied towards Project Costs prior to the Project Completion Date, (iv) Cash Flow applied or committed to be applied to Development Expenditure that is not committed under the Base Case Forecast or otherwise committed to fund development of Project Costs, (v) any Drawstop Equity Contributions, to the extent not reimbursed pursuant to Section 11.2(c) (Certain Restricted Payments) and (vi) following the Project Completion Date, Cash Flows applied towards other capital expenditures in respect of the Project Facilities; provided that such Cash Flows following the Project Completion Date would qualify to be distributed as Restricted Payments based on meeting the conditions set forth in Section 11.1 (Conditions to Restricted Payments) of the Common Terms Agreement or are otherwise eligible to be used for Required Capital Expenditures.

 

-175-

Calcasieu Pass - Common Terms Agreement


Equity Interests” means any and all shares, interests, participations or other equivalents (however designated) of capital stock of a corporation, any and all equivalent ownership interests in a Person (other than a corporation), including partnership interests and membership interests, and any and all warrants, rights or options to purchase or other arrangements or rights to acquire any of the foregoing.

ERISA” means the Employee Retirement Income Security Act of 1974.

ERISA Affiliate” means any Person, or trade or business that is a member of any group of organizations: (a) described in Section 414(b), (c), (m) or (o) of the Code of which the Borrower is a member and (b) solely for purposes of potential liability under Section 302(b) of ERISA and Section 412(b) of the Code and the lien created under Section 303(k) of ERISA and Section 430(k) of the Code, described in Section 414(m) or (o) of the Code of which a Obligor is a member.

ERISA Event” means:

 

  (a)

any “reportable event,” as defined in Section 4043 of ERISA or the regulations issued thereunder with respect to a Plan, other than events for which the 30-day notice period has been waived by current regulation under PBGC Regulation Subsections .27, .28, .29 or .31;

 

  (b)

the failure with respect to any Plan to meet the minimum funding requirements of Section 412 or 430 of the Code or Section 302 or 303 of ERISA, whether or not waived;

 

  (c)

the filing pursuant to Section 412(c) of the Code or Section 303 of ERISA of an application for a waiver of the minimum funding standard with respect to any Plan;

 

  (d)

the incurrence by a Obligor or any of its ERISA Affiliates of any liability under Title IV of ERISA with respect to the termination of any Plan;

 

  (e)

the filing of notice of intent to terminate a Plan or the treatment of a Plan amendment as a termination under Section 4041 of ERISA;

 

  (f)

the institution of proceedings to terminate a Plan by PBGC or to appoint a trustee to administer any Plan;

 

  (g)

the withdrawal by a Obligor or any of its ERISA Affiliates from a multiple employer plan (within the meaning of Section 4064 of ERISA) during a plan year in which it was a “substantial employer,” as such term is defined under Section 4064 of ERISA, upon the termination of a Multiemployer Plan or the cessation of operations under a Plan pursuant to Section 4062(e) of ERISA;

 

-176-

Calcasieu Pass - Common Terms Agreement


  (h)

the incurrence by a Obligor or any of its ERISA Affiliates of any liability with respect to the withdrawal or partial withdrawal from any Multiemployer Plan;

 

  (i)

the attainment of any Plan of “at risk” status within the meaning of Section 430 of the Code or Section 303 of ERISA;

 

  (j)

the receipt by a Obligor or any ERISA Affiliate of any notice, or the receipt by any Multiemployer Plan from a Obligor or any ERISA Affiliate of any notice, concerning the imposition of Withdrawal Liability or a determination that a Multiemployer Plan is, or is expected to be, insolvent or in critical, endangered or seriously endangered status, within the meaning of the Code or Title IV of ERISA;

 

  (k)

the failure of a Obligor or any ERISA Affiliate to pay when due any amount that has become liable to the PBGC, any Plan or trust established thereunder pursuant to Title IV of ERISA or the Code;

 

  (l)

the adoption of an amendment to a Plan requiring the provision of security to such Plan pursuant to Section 436(f) of the Code;

 

  (m)

a Obligor engages in a “prohibited transaction” within the meaning of Section 4975 of the Code or Section 406 of ERISA that is not otherwise exempt by statute, regulation or administrative pronouncement; or

 

  (n)

the imposition of a lien under ERISA or the Code with respect to any Plan or Multiemployer Plan.

EU Bail-In Legislation Schedule” means the EU Bail-In Legislation Schedule published by the Loan Market Association (or any successor Person), as in effect from time to time.

Event of Default” means a Loan Facility Event of Default, an Indenture Event of Default or any comparable Obligor event of default under any other Senior Debt Instrument entered into after the date of the Common Security and Account Agreement.

Event of Loss” means any event that causes any Project Facilities, or any portion thereof to be damaged, destroyed or rendered unfit for normal use for any reason whatsoever and, in each case, shall include an Event of Taking.

Event of Taking” means any taking, seizure, confiscation, requisition, exercise of rights of eminent domain, public improvement, inverse condemnation, condemnation or similar action of or proceeding by any Governmental Authority relating to all or any part of the Project Facilities, the Development, any Equity Interests in the Obligors or any other part of the Security Interests.

 

-177-

Calcasieu Pass - Common Terms Agreement


Excess Capacity LNG SPA” means the LNG Sales and Purchase Agreement (FOB) between the Borrower and Venture Global Commodities, LLC, dated as of November 14, 2018, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement, dated as of June 24, 2019.

Excluded Accounts” means Excluded Unsecured Accounts and any escrow account established under each Material Construction Contract.

Excluded Assets” has the meaning given in Section 3.2(g) (Security Interests to be Granted by the Obligors Excluded Assets) of the Common Security and Account Agreement.

Excluded Swap Obligation” means, with respect to any Obligor, any Swap Obligation if, and to the extent that, all or a portion of the guarantee of such Obligor of, or the grant by such Obligor of a security interest to secure, such Swap Obligation (or any guarantee thereof) is or becomes illegal under the Commodity Exchange Act or any rule, regulation or order of the Commodity Futures Trading Commission (or the application or official interpretation of any thereof) by virtue of such Obligor’s failure for any reason to constitute an “eligible contract participant” as defined in the Commodity Exchange Act and the regulations thereunder at the time the guarantee of such Obligor or the grant of such security interest becomes effective with respect to such Swap Obligation. If a Swap Obligation arises under a master agreement governing more than one swap, such exclusion shall apply only to the portion of such Swap Obligation that is attributable to swaps for which such guarantee or security interest is or becomes illegal.

Excluded Tax” means any of the following Taxes imposed on or with respect to a Finance Party or required to be withheld or deducted from a payment to a Finance Party:

 

  (a)

Taxes imposed on or measured by net income (however denominated), franchise Taxes, and branch profits Taxes, in each case, (i) imposed as a result of such Finance Party being organized under the laws of, or having its principal office or, in the case of any Facility Lender, its applicable lending office located in, the jurisdiction imposing such Tax (or any political subdivision thereof) or (ii) that are Other Connection Taxes;

 

  (b)

in the case of a Facility Lender, US federal withholding tax imposed on amounts payable to such Facility Lender pursuant to a law in effect at the time such Facility Lender becomes a party to a Facility Agreement or designates a new lending office (other than pursuant to an assignment or new lending office designation request by the Borrower), except to the extent that such Facility Lender (or its assignor, if any) was entitled, at the time of such designation of a new lending office (or assignment), to receive additional amounts from the Borrower with respect to such withholding tax pursuant to the Facility Agreement provisions described in Section 21.1 (Withholding Tax Gross-Up) of the Common Terms Agreement;

 

-178-

Calcasieu Pass - Common Terms Agreement


  (c)

Taxes attributable to a Facility Lender’s failure to comply with the provisions described in Section 21.5 (Status of Facility Lenders and Facility Agents) of the Common Terms Agreement; or

 

  (d)

US federal withholding Taxes imposed under FATCA.

Excluded Unsecured Accounts” has the meaning given in Section 3.2(g)(iv) (Security Interests to be Granted by the Obligors Excluded Assets) of the Common Security and Account Agreement.

Existing Facility Lender” has the meaning given in Section 19.6 (Transfers by a Facility Lender) of the Common Terms Agreement.

Expansion” has the meaning given in Section 7.2(a) (Expansion Contracts) of the Common Terms Agreement.

Export Authorization” means a long-term, multi-contract authorization issued by the DOE to export LNG from the LNG Facility, including the FTA Authorization and the Non-FTA Authorization.

Export Authorization Remediation” has the meaning given in Section 8.2(a)(ii)(A) (LNG SPA Mandatory Prepayment) of the Common Terms Agreement.

Facility Agent” means the facility agent under any Facility Agreement.

Facility Agreements” means the Credit Facility Agreement and any individual loan facility agreements (not including any Indenture or facility agreement for a “term loan B” financing that the Borrower has elected to treat as an Indenture) evidencing permitted Replacement Senior Debt and Working Capital Debt (and for which the Facility Agents have acceded to the Common Terms Agreement and to the Common Security and Account Agreement), in each case as required thereby, and “Facility Agreement” shall have a corresponding meaning.

Facility Debt Commitment” means the aggregate principal amount of Loans and letters of credit any Facility Lender is committed to disburse to or issue on behalf of the Borrower under any Facility Agreement.

Facility Debt Obligations” means the Senior Debt Obligations arising under the Facility Agreements.

Facility Lenders” means the Credit Facility Lender Parties and the lenders and issuing banks under any other Facility Agreements entered into after the Closing Date, and “Facility Lender” shall have a corresponding meaning.

 

-179-

Calcasieu Pass - Common Terms Agreement


Fair Labor Standards Act” means the Fair Labor Standards Act of 1938.

FATCA” means Sections 1471 through 1474 of the Code, as of the Closing Date (or any amended or successor version that is substantively comparable and not materially more onerous to comply with), any current or future regulations or official interpretations thereof and any agreement entered into pursuant to Section 1471(b)(1) of the Code.

Federal Reserve Bank” means each of the 12 Reserve Banks under the United States Federal Reserve System, or any successor thereto.

Federal Reserve Board” means the Board of Governors of the United States Federal Reserve System, or any successor thereto.

Fee Letters” means the Intercreditor Agency Fee Letter, the Account Bank Fee Letter, the Collateral Agent Fee Letter, the Credit Facility Agency Fee Letter, the Documentation Bank Fee Letters and any other similar fee letter, fee agreement or other fee arrangement between an Obligor and a Facility Agent, or between an Obligor and any of the Account Bank, Intercreditor Agent, Collateral Agent, Credit Facility Agent or other Facility Agent or Facility Lender that may be entered into from time to time after the date of the Common Security and Account Agreement.

FERC” means the US Federal Energy Regulatory Commission.

FERC Order” means that order issued by FERC on February 21, 2019 granting authorizations under Section 3 and Section 7 of the Natural Gas Act, in FERC Docket Nos. CP15-550-000, et al. at 166 FERC ¶ 61,144 (2019).

Final Completion” has the meaning given in the EPC Contract.

Final Maturity Date” means, with respect to each of the Facility Agreements, the date on which all Senior Debt under such Facility Agreement comes due, whether upon acceleration or otherwise.

Finance Documents” means, together, each of the following documents:

 

  (a)

the Common Terms Agreement;

 

  (b)

the Common Security and Account Agreement;

 

  (c)

the individual Facility Agreements;

 

  (d)

any Indenture;

 

  (e)

the Security Documents;

 

  (f)

the Direct Agreements;

 

-180-

Calcasieu Pass - Common Terms Agreement


  (g)

the Senior Notes;

 

  (h)

the Intercreditor Agreement;

 

  (i)

any fee letters with parties providing financing (other than any Equity Funding);

 

  (j)

any Permitted Senior Debt Hedging Instrument; and

 

  (k)

any other document the Intercreditor Agent (acting on the instructions of the Requisite Intercreditor Parties) designates, with the consent of the Borrower (such consent not to be unreasonably withheld), a Finance Document;

provided that when used with respect to the Facility Lenders, such term shall not include any Indenture or Senior Notes and when used with respect to the Senior Notes, such term shall not include the Common Terms Agreement, Facility Agreement or any other Finance Document to which the Indenture Trustee is not a party or under which security is not intended to be granted for the benefit of the Senior Notes.

Finance Party” means each Facility Lender, the Intercreditor Agent, the Collateral Agent, each Senior Creditor Group Representative (in its own right and in its capacity as agent), each Hedging Bank and the Account Bank.

First of Month Index” means a price which represents the most commonly traded fixed price at a major trading point and as published by Inside FERC Gas Market Report (“IFERC” or any successor publication widely used to establish index pricing in the US natural gas trading market).

First Repayment Date”, with respect to the Credit Facility Agreement, has the meaning given in the Credit Facility Agreement.

Fitch” means Fitch Ratings Ltd. or any successor thereto.

Fixed Facility Charge” has the meaning given in the applicable LNG SPA.

Fixed-Floating Futures Swap” means a contract which entitles the buyer of the contract to pay a fixed price for natural gas and the seller to pay a floating price equal to the final settlement price of the Futures Contract settlement prices. The Fixed-Floating Futures Swap shall be settled financially, via exchange of cash payment at the expiration of the underlying Futures Contract, rather than physically.

Fixed Projected DSCR” means, for each Quarterly Payment Date during the applicable period beginning no earlier than the First Repayment Date, the ratio of:

 

-181-

Calcasieu Pass - Common Terms Agreement


  (a)

the Cash Flow Available for Debt Service projected for such period, calculated solely to reflect (i) the Fixed Facility Charge under each of the Qualifying LNG SPAs then in effect, (ii) expected interest and investment earnings paid to the Obligors during such period, (iii) amounts expected to be paid to the Obligors during such period as Business Interruption Insurance Proceeds and (iv) the fixed expenses that could reasonably be expected to be incurred by the Obligors if the Material Project Counterparties were not lifting any cargoes under the Qualifying LNG SPAs; to

 

  (b)

Senior Debt Obligations projected to be paid in such period (taking into account Permitted Hedging Instruments) (other than (i) pursuant to voluntary prepayments or mandatory prepayments, (ii) Senior Debt due at maturity, (iii) Working Capital Debt, and (iv) Hedging Termination Amounts.

Flood Certificate” has the meaning given in Section 4.1(t)(i) (Conditions to Closing Date and Initial Advance – Flood Insurance) of the Common Terms Agreement.

Flood Program” has the meaning given in Section 4.1(t)(i)(C) (Conditions to Closing Date and Initial Advance – Flood Insurance) of the Common Terms Agreement.

FOB” means Free on Board as defined in Incoterms 2010.

FTA Authorization” means the DOE/FE Order Nos. 3345 in Docket No. 13-69- LNG (Sept. 27, 2013), 3520 in Docket No. 14-88-LNG (Oct. 10, 2014), and 3662 in Docket No. 15-25-LNG (June 17, 2015), granting the Borrower long-term, multi-contract authorization to export LNG by vessel from the LNG Facility to any country which has, or in the future develops, the capacity to import LNG via ocean-going vessels and with which the United States has, or in the future enters into, a free trade agreement requiring national treatment for trade in natural gas.

Fund” means any Person that is (or will be) engaged in making, purchasing, holding or otherwise investing in commercial loans and similar extensions of credit.

Futures Contract” means a contract which entitles the buyer of the contract to claim physical delivery of natural gas from the seller at a specified contract delivery point at a specified date in the future and entitles the seller to deliver the physical commodity to the buyer under the same conditions. The price between the buyer and the seller shall be transacted at the price of final settlement on a monthly basis.

GAAP” means generally accepted accounting principles in the jurisdiction in which the relevant party’s financial statements are prepared or International Accounting Standards/International Financial Reporting Standards, as in effect from time to time.

 

-182-

Calcasieu Pass - Common Terms Agreement


Galp” means Galp Energia E&P B.V.

Gas” means any hydrocarbon or mixture of hydrocarbons consisting essentially of methane and other paraffinic hydrocarbons and non-combustible gases in a gaseous state.

Gas Hedge Provider” means any party (other than the Obligors or their Affiliates) that is a party to a Gas Hedging Instrument that is secured pursuant to the Security Documents.

Gas Hedging Instruments” means Gas swaps, options contracts, futures contracts, options on futures contracts, caps, floors, collars or any other similar arrangements entered into by any Obligor related to movements in Gas prices.

Gas Sourcing Plan” means the plan set forth in Schedule K (Gas Sourcing Plan) of the Common Terms Agreement, as updated semi-annually by delivery by the Borrower of an updated plan, and related attachments and exhibits, by the Borrower to the Intercreditor Agent.

Gas Supply Agreement” means the NAESB Base Contract for Sale and Purchase of Natural Gas, dated as of April 18, 2019, by and between Indigo Minerals LLC and the Borrower, together with the Transaction Confirmation, dated as of April 18, 2019, and the Special Provisions to the Base Contract for Sale and Purchase of Natural Gas, dated as of April 18, 2019, by and between Indigo Minerals LLC and the Borrower, together with the Guaranty Agreement, dated as of April 18, 2019, by Indigo Natural Resources LLC in favor of the Borrower.

Gas Transportation Agreements” means:

 

  (a)

the Precedent Agreement, dated as of November 14, 2018, by and between Texas Eastern Transmission, LP and the Borrower, as superseded by the service agreement described therein;

 

  (b)

the Amended and Restated Precedent Agreement for Firm Natural Gas Transportation Service, dated as of December 21, 2018, by and between ANR Pipeline Company and the Borrower, as superseded by the service agreement described therein; and

 

  (c)

the Precedent Agreement for Firm Natural Gas Transportation Service, dated as of May 13, 2019, by and between Bridgeline Holdings, L.P., EnLink Midstream Operating, LP, Sabine Pipe Line LLC and the Borrower, as superseded by the service agreement described therein.

 

-183-

Calcasieu Pass - Common Terms Agreement


Government Rule” means any statute, law, regulation, ordinance, rule, judgment, order, decree, directive, requirement of, or other governmental restriction or any similar binding form of decision of or determination by, or any interpretation or administration of any of the foregoing by, any Governmental Authority, including all common law, which is applicable to any Person, whether now or hereafter in effect.

Governmental Authorities” means all supra-national, federal, state and local authorities or bodies including in each case any and all agencies, branches, departments and administrative and other subdivisions thereof, and all officials, agents and representatives of each of the foregoing, and “Governmental Authority” shall have a corresponding meaning.

Guarantor” means TransCameron Pipeline, LLC, a limited liability company organized under the laws of the State of Delaware, which is a direct wholly owned Subsidiary of the Pledgor, and any Subsidiary of the Borrower that accedes to the Common Security and Account Agreement from time to time as permitted under the Finance Documents then in effect as a Guarantor for the benefit of all Senior Creditors, pursuant to Section 11.15 (Additional Guarantors) of the Common Security and Account Agreement.

Hague Securities Convention” means the Convention on the Law Applicable to Certain Rights in Respect of Securities Held with an Intermediary (concluded July 5, 2006), which became effective in the United States on April 1, 2017.

Hazardous Materials” means:

 

  (a)

petroleum or petroleum byproducts, flammable materials, explosives, radioactive materials, friable asbestos, urea formaldehyde foam insulation and polychlorinated biphenyls;

 

  (b)

any chemicals, other materials, substances or wastes that are now or hereafter become defined as or included in the definition of “hazardous substances,” “hazardous wastes,” “hazardous materials,” “extremely hazardous wastes,” “restricted hazardous wastes,” “toxic substances,” “toxic pollutants,” “contaminants,” “pollutants” or words of similar import under any Environmental Law; and

 

  (c)

any other chemical, material, substance or waste that is now or hereafter regulated under or with respect to which liability may be imposed under Environmental Laws.

 

-184-

Calcasieu Pass - Common Terms Agreement


Hedging Bank” means a Person that is a counterparty to a Permitted Hedging Instrument with the Borrower and that has entered into or that accedes to the Common Security and Account Agreement, and:

 

  (a)

as of the date of entry into or assignment of any Permitted Hedging Instrument, any of the following: (i) any Senior Creditor, lead arranger or agent, as of the date of the Common Terms Agreement or as of such date, or (ii) any Affiliate of any Person listed in the foregoing sub-clause (a)(i) of this definition; or

 

  (b)

as of the date of entry into or assignment of any Permitted Hedging Instrument, (i) any Approved Bank or (ii) any Person whose obligations under such Permitted Hedging Instrument are guaranteed by an Approved Bank or any Person listed in clause (a) of this definition.

Hedging Excess Amount” has the meaning given in Section 12.22(c) (Hedging Arrangements) of the Common Terms Agreement.

Hedging Instruments” means:

(a) Interest Rate Hedging Instruments;

(b) Gas Hedging Instruments; and

(c) such other derivative transactions of a similar nature that any Obligor enters into to hedge risks of any commercial nature.

Hedging Termination Amount” means any Permitted Hedging Liability due as a result of the termination of a Permitted Hedging Instrument and/or the termination of any transaction entered into thereunder.

Historical DSCR” means, for each applicable measurement period, the ratio of (a) Cash Flow Available for Debt Service for such measurement period to (b) Debt Service for such measurement period (other than (i) pursuant to voluntary prepayments or mandatory prepayments, (ii) Senior Debt due at maturity, (iii) Working Capital Debt and (iv) Hedging Termination Amounts.

Illegality Event” has the meaning given in Section 19.5(b) (Mitigation Obligations; Replacement of Lenders) of the Common Terms Agreement.

Impairment” means, with respect to any Permit:

 

  (a)

the rescission, revocation, staying, withdrawal, early termination, cancellation, repeal or invalidity thereof or otherwise ceasing to be in full force and effect;

 

  (b)

the suspension or injunction thereof; or

 

-185-

Calcasieu Pass - Common Terms Agreement


  (c)

the inability to satisfy in a timely manner its stated conditions to effectiveness.

Impair” and “Impaired” shall have a corresponding meaning.

Indebtedness” of any Person, at any date, means:

 

  (a)

all obligations to repay borrowed money;

 

  (b)

all obligations to pay money evidenced by bonds, debentures, notes, banker’s acceptances, loan agreements or other similar instruments;

 

  (c)

all obligations to pay the deferred purchase price of property or services (excluding current accounts payable incurred in the ordinary course of business);

 

  (d)

all capital lease obligations of such Person;

 

  (e)

all obligations, contingent or otherwise, issued for the account of such Person, in respect of letters of credit, bank guarantees, surety bonds, letters of guarantee and similar instruments;

 

  (f)

all obligations of such Person under any Hedging Instruments (including any Hedging Termination Amounts);

 

  (g)

all guarantees by such Person of Indebtedness of others;

 

  (h)

any obligations of such Person to purchase or repurchase securities or other property which arises out of or in connection with the sale of the same or substantially similar securities or property;

 

  (i)

all obligations under conditional sale or other title retention agreements related to property acquired by such Person (even though the rights and remedies of the seller or lender under such agreement in the event of default are limited to repossession or sale of property or are otherwise limited in recourse);

 

  (j)

all Indebtedness of others secured by (or for which the holder of such Indebtedness has an existing right, contingent or otherwise, to be secured by) any Lien on property owned or acquired by such Person, whether or not the Indebtedness secured thereby has been assumed;

 

  (k)

all obligations to purchase, redeem, retire, defease or otherwise make any payment in respect of any Equity Interests of such Person or any other Person or any warrants, rights or options to acquire such equity interests, which in the case of redeemable preferred interests, being valued at the greater of its voluntary or involuntary liquidation preference plus accrued and unpaid dividends; and

 

-186-

Calcasieu Pass - Common Terms Agreement


  (l)

all Indebtedness of any other entity (including any partnership in which such Person is a general partner) to the extent such Person is liable therefor as a result of such Person’s ownership interest in or other relationship with such entity, except to the extent the terms of such Indebtedness provide that such Person is not liable therefor.

Indemnified Taxes” means (a) Taxes, other than Excluded Taxes, imposed on or with respect to any payment made by or on account of any obligation of a Obligor under or in connection with any Finance Document (other than any Indenture or Senior Notes) and (b) to the extent not otherwise described in clause (a) of this definition, Other Taxes.

Indenture” means any indenture to be entered into between the Borrower and the Indenture Trustee pursuant to which one or more series of Senior Notes will be issued, or, at the Borrower’s option, a facility agreement for a “term loan B” financing, pursuant to which Senior Debt will be incurred. No reference in any Finance Document to an Indenture or the Senior Notes or a “term loan B” shall mean or imply that entry into an Indenture or issuance of the Senior Notes or entry into a “term loan B” is required. For the avoidance of doubt, if at any time Senior Notes have not been issued or are not outstanding and there is no “term loan B”, any reference to satisfaction of the requirements of any Indenture or Senior Notes or the “term loan B” (and any reference to an Indenture Trustee) shall be ignored.

Indenture Declared Default” means an Indenture Event of Default which is declared by the Indenture Trustee (acting on behalf of the Senior Noteholders in accordance with such Indenture) to be an event of default under an Indenture or is otherwise deemed to have been declared to be an event of default in accordance with the terms of the Indenture.

Indenture Event of Default” means any of the events of default set out in an Indenture and defined as “Indenture Events of Default.”

Indenture Projected Fixed DSCR” has the meaning given in the applicable Indenture.

Indenture Trustee” means any trustee appointed in the role of indenture trustee under any Indenture or, with respect to a “term loan B” financing that the Borrower has elected to be treated as an Indenture, any administrative or other facility agent.

Independent Accountants” means any independent firm of accountants of recognized standing in the relevant jurisdiction.

Independent Engineer” means Lummus Consultants International, Inc. or any replacement independent engineering consulting firm selected in accordance with Section 13.2 (Replacement and Fees) of the Common Terms Agreement.

 

-187-

Calcasieu Pass - Common Terms Agreement


Index Swap” means a contract which entitles the buyer of the contract to pay one index price (e.g. First of Month Index) and entitles the seller to pay a different index price (e.g. the daily average). The index swap is settled financially via exchange of cash payment at the expiration of the underlying Futures Contract.

Individual Senior Noteholder Secured Accounts” has the meaning given in Section 3.2(c) (Security Interests to be Granted by the Obligors – Security Interests – Individual Senior Noteholder Secured Accounts) of the Common Security and Account Agreement.

Industry Standards” means the technical standards promulgated by the American Petroleum Institute, the American Gas Association, the American Society of Mechanical Engineers, the ASTM (formerly the American Society for Testing and Materials), or the National Fire Protection Association (NFPA).

Initial Advance” means the first Advance of the Term Loans in an aggregate amount equal to $75 million on the Closing Date following the satisfaction or waiver of the conditions precedent in Sections 4.1 (Conditions to Closing Date and Initial Advance) and 4.2 (Conditions to Each Advance) of the Common Terms Agreement in accordance with Section 4.4 (Satisfaction of Conditions) of the Common Terms Agreement.

Initial Coordinating Lead Arranger” has the meaning given in Exhibit A (Definitions) to the Credit Facility Agreement.

Initial LNG Buyers” means Shell, Edison, Galp, BP, Repsol and PGNIG. “Initial LNG SPA Guarantees” means:

 

  (a)

the Guarantee, dated as of February 4, 2016, by Shell Oil Company in favor of the Borrower, as amended by First Amendment to Guarantee, dated as of March 5, 2018;

 

  (b)

the Guarantee, dated as of May 17, 2018, by BP International Limited in favor of the Borrower;

 

  (c)

the Guarantee, dated as of May 18, 2018, by Galp Energia, SGPS, S.A. in favor of the Borrower;

 

  (d)

the Guarantee, dated as of August 14, 2018, by Repsol Exploracion, S.A. in favor of the Borrower; and

 

  (e)

Any other guarantee delivered to the Borrower under an Initial LNG SPA.

Initial LNG SPAs” means the following LNG SPAs entered into between the Borrower and the Initial LNG Buyers on or before the Closing Date:

 

-188-

Calcasieu Pass - Common Terms Agreement


  (a)

the Amended and Restated LNG Sales and Purchase Agreement (FOB) between the Borrower and Shell, dated as of April 4, 2018, as amended by First Amendment to Amended and Restated LNG Sales and Purchase Agreement (FOB), dated as of August 10, 2018, and Second Amendment to Amended and Restated LNG Sales and Purchase Agreement (FOB), dated as of June 14, 2019;

 

  (b)

the LNG Sales and Purchase Agreement (FOB) between the Borrower and Edison, dated as of September 25, 2017, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of February 28, 2018, Amendment No. 2 to LNG Sales and Purchase Agreement (FOB), dated as of June 13, 2018, Amendment No. 3 to LNG Sales and Purchase Agreement (FOB), dated as of December 13, 2018, and Amendment No. 4 to LNG Sales and Purchase Agreement (FOB), dated as of June 10, 2019, and supplemented by Waiver of Condition Precedent, dated as of September 4, 2018, by Edison;

 

  (c)

the LNG Sales and Purchase Agreement (FOB) between the Borrower and Galp, dated as of April 30, 2018, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of December 20, 2018;

 

  (d)

the LNG Sales and Purchase Agreement (FOB) between the Borrower and BP, dated as of May 17, 2018;

 

  (e)

the LNG Sales and Purchase Agreement (FOB) between the Borrower and Repsol, dated as of August 14, 2018, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of June 10, 2019; and

 

  (f)

the LNG Sales and Purchase Agreement (FOB) between the Borrower and PGNIG, dated as of September 28, 2018; and

 

  (g)

the Excess Capacity LNG SPA.

Initial Permitted Senior Debt Hedging Instrument” means each Permitted Senior Debt Hedging Instrument identified as such in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement as of the Closing Date.

Initial Senior Creditor” means each Senior Creditor under an Initial Senior Debt Instrument or an Initial Permitted Senior Debt Hedging Instrument as set forth in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement as of the Closing Date.

 

-189-

Calcasieu Pass - Common Terms Agreement


Initial Senior Creditor Group Representative” means a Senior Creditor Group Representative that is a party to the Common Terms Agreement as of the date of its execution and which is identified as such on Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement.

Initial Senior Debt” means the Senior Debt Obligations owing under the Credit Facility Agreement.

Initial Senior Debt Commitments” means the Senior Debt Commitments identified as such in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement as of the Closing Date.

Initial Senior Debt Instrument” means each Senior Debt Instrument identified as such in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement as of the Closing Date.

Initial Senior Debt Obligations” means the Senior Debt Obligations under the Initial Senior Debt Instruments.

Initiating Percentage” means Senior Creditor Group Representatives representing the following percentages of the principal amount of Senior Debt Obligations outstanding during the following periods (or, if no Senior Debt is outstanding, commitments in respect thereof):

 

  (a)

with respect to any Payment Default:

 

  (i)

at least 66.7% prior to 30 days following the occurrence of a Payment Default or the declaration thereof, as the case may be;

 

  (ii)

greater than 50% on or after 30 days and prior to 120 days following the occurrence of a Payment Default or the declaration thereof, as the case may be; and

 

-190-

Calcasieu Pass - Common Terms Agreement


  (iii)

the lesser of $100 million or 5% of the outstanding Senior Debt held by any individual Senior Creditor Group, on or after 120 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof, as the case may be; and

 

  (b)

with respect to any other Event of Default:

 

  (i)

at least 66.7% on or prior to 30 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof, as the case may be;

 

  (ii)

greater than 50% on or after 30 days and prior to 180 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof, as the case may be; and

 

  (iii)

the lesser of $100 million or 5% of the outstanding Senior Debt held by any individual Senior Creditor Group, on or after 180 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof, as the case may be.

Insurance” shall mean (a) all insurance policies covering any or all of the Collateral (regardless of whether the Collateral Agent is the loss payee thereof) and (b) any key man life insurance policies.

Insurance Advisor” means Moore-McNeil, LLC or any independent replacement insurance consulting firm to be selected in accordance with Section 13.2 (Replacement and Fees) of the Common Terms Agreement.

Insurance/Condemnation Proceeds Account” is the account described in Section 4.3(a)(x) (Accounts) of the Common Security and Account Agreement.

Insurance Proceeds” means all proceeds of any insurance policies required pursuant to the Schedule of Minimum Insurance or otherwise obtained with respect to the Development that are paid or payable to or for the account of the Obligors as loss payee (other than Business Interruption Insurance Proceeds and proceeds of insurance policies relating to third party liability).

Intellectual Property” means the collective reference to all rights, priorities and privileges relating to intellectual property, whether arising under the United States, multinational or foreign laws or otherwise, including Copyrights, Copyright Licenses, Patents, Patent Licenses, Trademarks, Trademark Licenses, Trade Secrets, and Trade Secret Licenses, and all rights to sue or otherwise recover for any past, present and future infringement, dilution, misappropriation, or other violation or impairment thereof, including the right to receive all proceeds therefrom, including license fees, royalties, income, payments, claims, damages and proceeds of suit, now or hereafter due and/or payable with respect thereto.

 

-191-

Calcasieu Pass - Common Terms Agreement


Intercreditor Agent” means the intercreditor agent appointed pursuant to the Intercreditor Agreement.

Intercreditor Agency Fee Letter” means the fee letter entered into between the Company and the Intercreditor Agent in respect of the fees payable to the Intercreditor Agent in respect of its services to be performed as more fully described in the Common Security and Account Agreement and the other Security Documents.

Intercreditor Agreement” means the Intercreditor Agreement, dated as of August 19, 2019, among the Intercreditor Agent, the Collateral Agent and the Facility Agents and Hedging Banks party thereto from time to time, setting forth the appointment of the Intercreditor Agent and setting forth voting and certain intercreditor arrangements among all Facility Lenders and Hedging Banks.

Interest Rate Hedging Instrument” means interest rate swaps, option contracts, futures contracts, options on futures contracts, caps, floors, collars or any other similar arrangements entered into by the Borrower related to interest rates.

International LNG Terminal Standards” means, to the extent not inconsistent with the express requirements of the Common Terms Agreement, the international standards and practices applicable to the design, construction, equipment, operation or maintenance of LNG receiving, exporting, liquefaction and regasification terminals, established by the following (such standards to apply in the following order of priority): (a) a Governmental Authority having jurisdiction over any Obligor, (b) the Society of International Gas Tanker and Terminal Operators (“SIGTTO”) (or any successor body of the same) and (c) any other internationally recognized non-governmental agency or organization with whose standards and practices it is customary for reasonable and prudent operators of LNG receiving, exporting, liquefaction and regasification terminals to comply. In the event of a conflict between any of the priorities noted above, the priority with the alphabetical priority noted above shall prevail.

International LNG Vessel Standards” means, to the extent not inconsistent with the express requirements of the Common Terms Agreement, the international standards and practices applicable to the ownership, design, equipment, operation or maintenance of LNG vessels established by: (a) the International Maritime Organization, (b) the Oil Companies International Marine Forum, (c) SIGTTO (or any successor body of the same), (d) the International Navigation Association, (e) the International Association of Classification Societies, and (f) any other internationally recognized agency or nongovernmental organization with whose standards and practices it is customary for reasonable and prudent operators of LNG vessels to comply. In the event of a conflict between any of the priorities noted above, the priority with the alphabetical priority noted above shall prevail.

 

-192-

Calcasieu Pass - Common Terms Agreement


Investment Company Act” means the United States Investment Company Act of 1940.

Investment Grade” means two long-term unsecured credit ratings that are equal to or better than (a) Baa3 by Moody’s, (b) BBB- by S&P, (c) BBB- by Fitch, or (d) any comparable credit ratings by any other nationally recognized statistical rating organizations.

Investment Grade LNG Buyer” means an LNG Buyer that (a) is Investment Grade, (b) has its obligations guaranteed by an Investment Grade entity or (c) for the purposes of LNG SPAs in Section 8.1(a) (LNG SPA Maintenance), Section 8.2(a)(i) (LNG SPA Mandatory Prepayment) or Section 11.1 (Conditions to Restricted Payments) of the Common Terms Agreement, has all of its obligations under the applicable LNG SPA supported by a letter of credit issued by an Acceptable Bank.

Issuance Request Form” means a Disbursement Request for issuance of letter(s) of credit, substantially in the form set forth in Schedule B-3 (Issuance Request Form (Letters of Credit)) to the Common Terms Agreement (or equivalent under another Senior Debt Instrument), given by the Borrower in accordance with the terms of the applicable Facility Agreement.

Issuing Banks” has the meaning given to it in Exhibit A (Definitions) to the Credit Facility Agreement.

Judgment Currency” has the meaning given in Section 12.3 (Judgment Currency) of the Common Security and Account Agreement.

Knowledge” means, with respect to any of the Obligors, the actual or constructive knowledge of any Person holding any of the positions (or successor position to any such position) set forth in Schedule T (Knowledge Parties) to the Common Terms Agreement; provided that each such Person shall be deemed to have knowledge of all events, conditions and circumstances described in any notice delivered to the Borrower pursuant to the terms of the Common Terms Agreement or any other Finance Document. “Knowingly” shall have a corresponding meaning.

LC Costs” means (a) fees, expenses and interest associated with Working Capital Debt and (b) any reimbursement by a Obligor of amounts paid under a letter of credit that is Working Capital Debt for expenditures that if paid by such Obligor directly would have constituted Operation and Maintenance Expenses.

LC Reimbursement Payment” has the meaning assigned to such term in the Credit Facility Agreement.

Leases” means:

 

-193-

Calcasieu Pass - Common Terms Agreement


  (a)

the Amended and Restated Ground Lease Agreement, dated as of June 20, 2019, by and between the Borrower and Henry Venture, LLC, amending and restating the Ground Lease Agreement dated as of March 11, 2019, as amended by that certain First Amendment to Ground Lease Agreement dated as of March 25, 2019; and

 

  (b)

the Amended and Restated Ground Lease Agreement, dated as of July 15, 2019, by and between the Borrower and JADP Venture, LLC, amending and restating the Ground Lease Agreement dated as of March 14, 2019, as amended by that certain First Amendment to Ground Lease Agreement dated as of March 25, 2019.

Lenders” has the meaning given in 23.20 (No Fiduciary Duty) of the Common Terms Agreement.

Lenders’ Reliability Test” means a 90-day test which demonstrates that the Project Facilities’ overall production during the applicable time periods can meet the applicable minimum cumulative LNG production volumes without exceeding a maximum amount of allowable downtime, in accordance with and as more specifically set forth in Schedule O (Lenders’ Reliability Test Criteria) to the Common Terms Agreement or as otherwise agreed among the Borrower, the Facility Lenders and the Independent Engineer.

Letters of Credit” has the meaning given in the Credit Facility Agreement.

LIBOR” has the meaning given in the Credit Facility Agreement.

Lien” means any mortgage, privilege, pledge, lien, charge, assignment, assignment by way of security, hypothecation or security interest securing any obligation of any Person, any restrictive covenant or condition, right reservation, right to occupy, encroachment, option, easement, servitude, right of way or other imperfection of title or encumbrance (including matters that would be shown on an accurate survey) burdening any real property or any other agreement or arrangement having the effect of conferring security howsoever arising.

Lien Waiver” means any Lien waiver contemplated by any Material Construction Contract.

LNG” means Gas in a liquid state at or below its boiling point at a pressure of approximately one atmosphere.

LNG Buyer” means the buyer under the applicable LNG SPA.

LNG Facility” means the approximately 10 MTPA nameplate LNG liquefaction and export project located alongside the Calcasieu Ship Channel in Cameron Parish, Louisiana, consisting of nine integrated single mixed refrigerant liquefaction blocks and supporting facilities, three natural gas pre-treatment units

 

-194-

Calcasieu Pass - Common Terms Agreement


to remove water and acid gases from feed gas prior to liquefaction (each capable of supporting 50% of the nameplate capacity), two 200,000 cubic meter cryogenic LNG storage tanks, a marine terminal with two LNG berthing docks that can accommodate vessels up to at least 185,000 cubic meters in capacity, a 620 megawatt air-cooled combined-cycle gas-fired power plant with an additional 25 megawatt gas-fired turbine with selective catalyst reduction, in each case (i) with related onsite utilities and supporting infrastructure and (ii) as such facilities may be improved, replaced, modified, changed or expanded in accordance with the Finance Documents.

LNG Facility Site” means the portion of the Site on which the LNG Facility is situated, as more fully described in the Leases.

LNG Production System RFSU” has the meaning given in the EPC Contract.

LNG SPA” means an LNG sale and purchase agreement between the Borrower and a buyer of LNG pursuant to which the Borrower will sell and the buyer will purchase LNG from the Borrower.

LNG SPA Force Majeure” means “Force Majeure” as defined in each Initial LNG SPA.

LNG SPA Mandatory Prepayment” has the meaning given in Section 8.2(a) (LNG SPA Mandatory Prepayment) of the Common Terms Agreement.

LNG SPA Prepayment Event” has the meaning given in Section 8.2(a) (LNG SPA Mandatory Prepayment) of the Common Terms Agreement.

Loan Facility Declared Default” means a Loan Facility Event of Default that is declared to be a default in accordance with Section 15.2 (Declaration of Loan Facility Declared Default) of the Common Terms Agreement.

Loan Facility Disbursement Accounts” are the Accounts described in Section 4.3(a)(i) (Accounts) of the Common Security and Account Agreement.

Loan Facility Event of Default” means any of the events set forth in Section 15.1 (Loan Facility Events of Default) of the Common Terms Agreement or any Obligor events of default under any Facility Agreement.

Loans” means the Senior Debt Obligations created under individual Facility Agreements to be made available by the Facility Lenders.

Local Accounts” has the meaning set forth in Section 4.12(a) (Local Accounts) of the Common Security and Account Agreement.

Louisiana Private Works Act” is the Louisiana Private Works Act, La. R.S. §§ 9:4801 et seq., and any successor provisions thereto.

 

-195-

Calcasieu Pass - Common Terms Agreement


LPS1” has the meaning given in the EPC Contract.

LPS2” has the meaning given in the EPC Contract.

LPS3” has the meaning given in the EPC Contract.

LTS Purchase Order” means that certain Purchase Order Contract for the Sale of Liquefaction Train System, dated as of September 25, 2018, by and between the Borrower and BHGE, as supplemented by Limited Notice to Proceed, dated as of September 25, 2018 and that letter agreement re: UOP Pre-Treatment System, dated June 24, 2019, by and between the Borrower and BHGE, and as amended by Change Order No. 1, dated as of June 24, 2019, by and between the Borrower and BHGE.

Majority in Interest of the Senior Creditors” with respect to any Decision at any time means Senior Creditors:

 

  (a)

whose share in the outstanding principal amount of the Senior Debt Obligations and whose undrawn Senior Debt Commitments are more than 50% of all of the outstanding principal amount of the Senior Debt Obligations and all the undrawn Senior Debt Commitments of all the Senior Creditors; or

 

  (b)

if there is no principal amount of Senior Debt Obligations then outstanding, Senior Creditors whose Senior Debt Commitments are more than 50% of the aggregate Senior Debt Commitments of all Senior Creditors.

Manager” shall mean Venture Global Services, LLC.

Mandatory Prepayment Senior Notes Account” has the meaning given in Section 4.3(a)(xi) (Accounts) of the Common Security and Account Agreement.

Margin Stock” means margin stock as defined in Regulation U of the Federal Reserve Board.

Marine Works Construction Agreement” means that certain Construction Agreement Relating to Marine Works, dated as of January 24, 2017, by and between the Borrower and Weeks Marine, as amended by Amendment No. 1 to Construction Agreement (Marine Works), dated as of December 13, 2017, Amendment No. 2 to Construction Agreement (Marine Works), dated as of October 5, 2018, Amendment No. 3 to Construction Agreement (Marine Works), dated as of March 5, 2019, Amendment No. 4 to Construction Agreement (Marine Works), dated as of June 28, 2019, and Amendment No. 5 to Construction Agreement (Marine Works), dated as of July 3, 2019, and supplemented by Anticipated LNTP, dated as of October 5, 2018, Limited Notice to Proceed No. 2 (Marine Works), dated as of February 22, 2019, Notice to Proceed, dated as of

 

-196-

Calcasieu Pass - Common Terms Agreement


July 3, 2019, and that certain letter agreement re: insurance requirements prior to financial closing Date, dated as of July 3, 2019, in each case, by and between the Borrower and Weeks Marine.

Market Consultant” means IHS Markit or any independent replacement marketing consulting firm to be selected in accordance with Section 13.2 (Replacement and Fees) of the Common Terms Agreement.

Market Terms” means terms consistent with or no less favorable to the applicable Obligor (as seller or buyer, as the case may be) than either: (a) any Required LNG SPAs then in effect or (b) the terms a non-Affiliated seller or buyer, as the case may be, of the relevant product could receive in an arm’s-length transaction based on then-current market conditions for transactions of a similar nature and duration and taking into account such factors as the characteristics of the goods and services, the market for such goods and services (including any applicable regulatory conditions), tax effects of the transaction, the location of the Project Facilities and the counterparties.

Material Adverse Effect” means a material adverse effect on:

 

  (a)

each Obligor’s ability to perform and comply with its material obligations under each Material Project Agreement then in effect and to which it is a party;

 

  (b)

the Obligors’ ability, taken as a whole, to perform their material obligations under the Finance Documents;

 

  (c)

the Borrower’s ability to pay its Senior Debt Obligations when due;

 

  (d)

the Security Interests created by or under the relevant Security Documents, taken as a whole in respect of the Obligors or the Project Facilities, including the material impairment of the rights of or benefits or remedies, taken as a whole, available to the Secured Parties; or

 

  (e)

the Obligors’ financial condition and results of operation, on a consolidated basis.

Material Construction Contracts” means, together, each of the following documents:

 

  (a)

the EPC Contract;

 

  (b)

the Pipeline Construction Contract;

 

  (c)

the LTS Purchase Order;

 

  (d)

the PIS Purchase Order;

 

-197-

Calcasieu Pass - Common Terms Agreement


  (e)

the Pretreatment Contract;

 

  (f)

the Marine Works Construction Agreement;

 

  (g)

the Storm Surge Wall Construction Agreement; and

 

  (h)

the Storage Tanks EPC Contract.

Material Project Agreements” means:

 

  (a)

the Initial LNG SPAs;

 

  (b)

the Initial LNG SPA Guarantees;

 

  (c)

the Material Construction Contracts;

 

  (d)

the Gas Transportation Agreements;

 

  (e)

from and after LNG Production System RFSU (as defined in the EPC Contract) with respect to LPS1, the Gas Supply Agreement;

 

  (f)

the Service Agreements (other than the agreement described in clause (e) of the definition thereof);

 

  (g)

from and after the entry into such agreement, the agreement described in clause (e) of the definition of “Service Agreements”;

 

  (h)

the Leases;

 

  (i)

the Parent Guarantees;

 

  (j)

the Access License Agreements;

 

  (k)

the Pipeline Service Agreements;

 

  (l)

any additional contract with obligations and liabilities thereunder (A) equal to or in excess of $20 million per year and a committed term of at least three (3) years, with respect to any contract for the purchase of natural gas by, or supply of natural gas to, the Borrower, (B) equal to or in excess of $50 million per year and a committed term of at least three (3) years, with respect to any contract for the delivery and sale of LNG by the Borrower, and (C) equal to or in excess of $50 million per year and a committed term of at least two (2) years, with respect to any other contract;

 

  (m)

any parent guarantee related to any agreement described in (e) or (k) above or, to the extent not described in (b) above, related to any Initial LNG SPA or Qualifying LNG SPA; and

 

-198-

Calcasieu Pass - Common Terms Agreement


  (n)

any replacement of any existing agreement described in (a) through (l) above.

With respect to any Indenture, “Material Project Agreements” will have the meaning given in such Indenture.

Material Project Counterparties” means each of the Construction Contractors, the Initial LNG Buyers, Shell Oil Company, Galp Energia, SGPS, S.A., BP International Limited, Repsol Exploracion, S.A., Texas Eastern Transmission, LP, ANR Pipeline Company, Bridgeline Holdings, L.P., EnLink Midstream Operating, LP, Sabine Pipe Line LLC, Indigo Minerals LLC, Calcasieu Pass Operations, LLC, Venture Global Services, LLC, TransCameron Operations, LLC, Henry Venture, LLC, JADP Venture, LLC, General Electric Company, McDermott International, Inc., Honeywell International Inc. and CP Marine Offloading, LLC.

Maturity Date” means August 19, 2026.

Minimum Insurance” means the insurance described in the Schedule of Minimum Insurance and required to be procured and maintained pursuant to Section 12.28 (Insurance Covenant) of the Common Terms Agreement.

Modification” means, with respect to any Finance Document, any amendment, supplement, waiver or other modification of the terms and provisions thereof and the term “Modify” shall have a corresponding meaning; provided, that with respect to Sections 7.2(b)(ii)(A), (B) and (C) (Modification Approval Levels – Modifications to Other Finance Documents) of the Common Security and Account Agreement, the exercise of any option, right or entitlement expressly set forth in the provisos to each such clause shall not be a Modification.

Moody’s” means Moody’s Investors Service, Inc. or any successor thereto.

Mortgage” means the Multiple Indebtedness Mortgage, Pledge of Leases and Rents and Security Agreement, from the Borrower to Venture Global LNG, Inc., as assigned on the Closing Date to the Collateral Agent pursuant to that certain Assignment of Multiple Indebtedness Mortgage, Pledge of Leases and Rents and Security Agreement between Venture Global LNG, Inc. and the Collateral Agent in connection with that certain Assignment of Intercompany Loan Agreement among Venture Global LNG, Inc., the Borrower, the Guarantor and the Credit Facility Agent, and as confirmed by that certain Confirmation of Multiple Indebtedness Mortgage, Pledge of Leases and Rents and Security Agreement by the Borrower in favor of the Collateral Agent.

Mortgaged Property” has the meaning given in Section 4.1(t)(i) (Conditions to Closing Date and Initial Advance – Flood Insurance) of the Common Terms Agreement.

 

-199-

Calcasieu Pass - Common Terms Agreement


MTPA” means million metric tonnes per annum.

Multiemployer Plan” means a “multiemployer plan” as defined in Section 3(37) of ERISA to which contributions have been made by any Obligor or any ERISA Affiliate in the past five years and which is covered by Title IV of ERISA.

Natural Gas Act” means the Natural Gas Act of 1938, as amended, and the regulations of FERC and DOE promulgated thereunder.

Net Cash Proceeds” means in connection with any asset disposition, the aggregate cash proceeds received by any Obligor in respect of any asset disposition (including any cash received upon the sale or other disposition of any non-cash consideration received in any asset disposition), net of the direct costs and expenses relating to such asset disposition and payments made to retire Indebtedness (other than the Senior Debt Obligations) required to be repaid in connection therewith, including legal, accounting and investment banking fees, and sales commissions, and any relocation expenses incurred as a result of such asset disposition, taxes paid or payable as a result of such asset disposition, in each case, after taking into account any available tax credits or deductions and amounts reserved for adjustment in respect of the sale price of such asset or assets established in accordance with GAAP.

New Facility Agent Accession Agreement (Additional Senior Debt)” has the meaning given in Section 19.4(b)(i) (Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement) of the Common Terms Agreement.

Non-Consenting Lender”, with respect to a Facility Agreement, has the meaning given in such Facility Agreement.

Non-Controlling Claimholders” means Senior Creditor Group Representatives who were not included in the Majority in Interest of the Senior Creditors who make up the Controlling Claimholders.

Non-FTA Authorization” means the DOE/FE Order No. 4346, issued on March 5, 2019, in Docket Nos. 13-69-LNG, 14-88-LNG, and 15-25-LNG, granting Borrower long-term, multi-contract authorization to export LNG by vessel from the LNG Facility to countries with which the United States has not entered into free trade agreements requiring national treatment for trade in natural gas and with which trade is not prohibited by United States law or policy.

Non-Recourse Parties” has the meaning given in Section 23.22 (Limited Recourse) of the Common Terms Agreement.

Non-Recourse Persons” has the meaning given in Section 10.3(a) (Limitation on Recourse) of the Common Security and Account Agreement.

 

-200-

Calcasieu Pass - Common Terms Agreement


Notice of Security Enforcement Action” has the meaning given in Section 6.2(f) (Initiation of Security Enforcement Action – Notice of Security Enforcement Action) of the Common Security and Account Agreement.

NYMEX” means the New York Mercantile Exchange, Inc., a wholly owned subsidiary of the CME Group Inc.

NYMEX Natural Gas Futures Contract” means the Futures Contract for natural gas on NYMEX, which is used for the physical receipt and/or delivery of gas at the Henry Hub located in Erath, Louisiana.

O&M Agreement” means an agreement between an Obligor and an Operator for the relevant Project Facilities.

Obligors” means the Borrower and the Guarantor.

OFAC” means the Office of Foreign Assets Control of the US Department of the Treasury.

OFAC Laws” means any laws, regulations, and executive orders relating to the economic sanctions programs administered by OFAC, including the International Emergency Economic Powers Act, 50 U.S.C. sections 1701 et seq.; the Trading with the Enemy Act, 50 App. U.S.C. sections 1 et seq.; and the Office of Foreign Assets Control, Department of the Treasury Regulations, 31 C.F.R. Parts 500 et seq. (implementing the economic sanctions programs administered by OFAC).

OFAC SDN List” means the list of “Specially Designated Nationals and Blocked Persons” maintained by OFAC.

Operating Account” is the Account described in Section 4.3(a)(vi) (Accounts) of the Common Security and Account Agreement.

Operating Budget” has the meaning given in Section 10.5(a) (Operating Budget) of the Common Terms Agreement, it being acknowledged and understood that the “Operating Budget” will be comprised of a budget in respect of the LNG Facility and a budget in respect of the TransCameron Pipeline and that all references in the Finance Documents to the “Operating Budget” shall be to such budgets collectively or to the budget applicable to the Project Facilities that are the subject of the applicable provision, as the context may require.

Operating Manual” means the operation, maintenance and spare parts manuals delivered by the EPC Contractor under the EPC Contract.

Operation and Maintenance Expenses” means, for any period, computed without duplication, in each case, costs and expenses of the Obligors that are contemplated by the then-effective Operating Budget or are incurred in connection with any permitted excess thereunder pursuant to Section 12.3 (Project Construction; Maintenance of Properties) of the Common Terms Agreement including:

 

-201-

Calcasieu Pass - Common Terms Agreement


  (a)

fees and costs of the Manager pursuant to the Administrative Services Agreements; plus

 

  (b)

amounts payable by the Obligors under a Material Project Agreement then in effect; plus

 

  (c)

expenses for operating the Development and maintaining it in good repair and operating condition payable during such period, including the ordinary course fees and costs of the Operators payable pursuant to the O&M Agreements; plus

 

  (d)

LC Costs; plus

 

  (e)

insurance costs payable during such period; plus

 

  (f)

applicable sales and excise taxes (if any) payable or reimbursable by the Obligors during such period; plus

 

  (g)

franchise taxes payable by the Obligors during such period; plus

 

  (h)

property taxes payable by the Obligors during such period; plus

 

  (i)

any other direct taxes (if any) payable by the Obligors to the taxing authority (other than any taxes imposed on or measured by income or receipts) during such period; plus

 

  (j)

costs and fees attendant to the obtaining and maintaining in effect the Permits payable during such period; plus

 

  (k)

expenses for spares and other capital goods inventory, capital expenses related to the construction and start-up of the Project Facilities, maintenance capital expenditures, including those required to maintain the Project Facilities’ capacity; plus

 

  (l)

legal, accounting and other professional fees of the Obligors payable during such period; plus

 

  (m)

Required Capital Expenditures; plus

 

  (n)

the cost of purchase, storage and transportation of Gas and electricity; plus

 

  (o)

all other cash expenses payable by the Obligors in the ordinary course of business.

 

-202-

Calcasieu Pass - Common Terms Agreement


Operation and Maintenance Expenses shall exclude, to the extent included above: (i) transfers from any Account into any other Account (other than the Operating Account) during such period, (ii) payments of any kind with respect to Restricted Payments during such period, (iii) depreciation for such period, and (iv) except as provided in clauses (j), (k) and (m) above, any capital expenditure.

To the extent amounts are advanced in accordance with the terms of the applicable Senior Debt Instrument, secured Permitted Hedging Instrument or other Indebtedness permitted under Section 12.14 (Limitation on Indebtedness) of the Common Terms Agreement for the payment of such Operation and Maintenance Expenses, the obligation to repay such advances shall itself constitute an Operation and Maintenance Expense.

Operational” means that all nine (9) of the blocks relating to the LNG Facility are mechanically complete, have passed the applicable acceptance tests and are operating in accordance with their performance guarantees, in each case, as set forth in the Material Construction Contracts.

Operator” means each of Calcasieu Pass Operations, LLC, a limited liability company organized under the laws of the State of Delaware, and TransCameron Operations, LLC, a limited liability company organized under the laws of the State of Delaware, as applicable.

Other Connection Taxes” means, with respect to any Finance Party, Taxes imposed as a result of a present or former connection between such Finance Party and the jurisdiction imposing such Tax (other than connections arising from such Finance Party having executed, delivered, become a party to, performed its obligations under, received payments under, received or perfected a security interest under, sold or assigned an interest in, or engaged in any other transaction pursuant to or enforced any Finance Document).

Other Taxes” means all present or future stamp, court or documentary, intangible, recording, filing or similar Taxes that arise from any payment made under, from the execution, delivery, performance, enforcement or registration of, from the receipt or perfection of a security interest under, or otherwise with respect to, any Finance Document (other than any Indenture or Senior Notes), except any such Taxes that are Other Connection Taxes imposed with respect to an assignment of a Facility Lender’s interest in a Facility Agreement (other than an assignment made pursuant to Section 19.5 (Mitigation Obligations; Replacement of Lenders) of the Common Terms Agreement).

Parent Guarantees” means:

 

  (a)

Seller Parent Guaranty Agreement, dated as of September 28, 2018, by General Electric Company for the benefit of the Borrower, relating to the LTS Purchase Order;

 

-203-

Calcasieu Pass - Common Terms Agreement


  (b)

Seller Parent Guaranty Agreement, dated as of September 28, 2018, by General Electric Company for the benefit of the Borrower, relating to the PIS Purchase Order;

 

  (c)

Parent Guarantee, dated as of August 5, 2019, by McDermott International, Inc., in favor of the Borrower;

 

  (d)

Parent Guarantee, dated as of December 21, 2018, by Honeywell International Inc. in favor of the Borrower; and

 

  (e)

the EPC Contract Guaranty.

Participant” means each Person (other than a natural Person, or a holding company, investment vehicle or trust for, or owned and operated for the primary benefit of, a natural Person) to whom a Facility Lender may sell participations from time to time.

Participant Register” means a register on which each Facility Lender which sells a participation, enters the name and address of each Participant and the principal amounts (and stated interest) of each Participant’s interest in the relevant Facility Agreement or other obligations under the Finance Documents. Each Facility Lender that sells a participation shall, acting solely for this purpose as a non- fiduciary agent of the Borrower, maintain a Participant Register.

Parties”, with respect to any agreement, means the signatories to such agreement.

Patent Licenses” means all agreements, licenses and covenants providing for the granting of any right in or to any Patent or otherwise providing for a covenant not to sue for infringement or other violation of any Patent (whether an Obligor is licensee or licensor thereunder) including each agreement required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Patent Licenses” (as such schedule may be amended or supplemented from time to time).

Patents” means all United States and foreign and multinational patents and certificates of invention, or similar industrial property rights, and applications for any of the foregoing, including:

 

  (a)

each patent and patent application required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Patents” (as such schedule may be amended or supplemented from time to time);

 

  (b)

all reissues, substitutes, divisions, continuations, continuations-in-part, extensions, renewals, and reexaminations thereof;

 

-204-

Calcasieu Pass - Common Terms Agreement


  (c)

all inventions and improvements described and claimed therein;

 

  (d)

all rights to sue or otherwise recover for any past, present and future infringement or other violation thereof;

 

  (e)

all proceeds of the foregoing, including license fees, royalties, income, payments, claims, damages, and proceeds of suit now or hereafter due and/or payable with respect thereto; and

 

  (f)

all other rights of any kind accruing thereunder or pertaining thereto throughout the world.

Payment Date” means each CTA Payment Date and any other date for payment of Senior Debt Obligations (including payment dates for the payment of interest) under or pursuant to any Senior Debt Instrument, including any Indenture, or Permitted Hedging Instrument.

Payment Default” means any event of default under Section 15.1(a) (Loan Facility Events of Default – Payment Default) of the Common Terms Agreement and any comparable provision in any Senior Debt Instrument then in effect entered into after the date of the Common Security and Account Agreement.

PBGC” means the Pension Benefit Guaranty Corporation established pursuant to Subtitle A of Title IV of ERISA (or any successor).

Pension Plan” means a Plan, other than a Multiemployer Plan, which is subject to Title IV of ERISA or Section 412 of the Code or Section 302 of ERISA.

Performance Liquidated Damages” means any liquidated damages resulting from the Project Facilities’ performance that are required to be paid by a Construction Contractor or any other counterparty to a Material Project Agreement for or on account of any diminution to the performance of the Project Facilities.

Performance Test” has the meaning given to such term in each Material Construction Contract.

Permit” means (a) any authorization, consent, approval, license, lease, ruling, tariff, rate, certification, waiver, exemption, filing, variance, claim, order, judgment or decree of, by or with, (b) any required notice to, (c) any declaration of or with, or (d) any registration by or with, in the cases of the foregoing clauses (a) through (d), any Governmental Authority and then required for the development, construction and operation of the Project Facilities as contemplated in the Finance Documents and the Material Project Agreements then in effect.

 

-205-

Calcasieu Pass - Common Terms Agreement


Permitted Additional Working Capital Debt” means any additional working capital debt incurred pursuant to Section 6.2 (Working Capital Debt); provided that, (1) no Event of Default or Unmatured Event of Default has occurred and is Continuing or could reasonably be expected to occur after giving effect to the incurrence of the Working Capital Debt and (2) any Senior Debt Instrument governing the additional working capital debt shall require the Borrower to reduce the principal amount relating to any revolving Loans thereunder to $0 for a period of at least five consecutive Business Days at least once per calendar year.

Permitted Completion Amount” means a sum equal to an amount certified by the Borrower (and confirmed reasonable by the Independent Engineer) on the Project Completion Date as necessary to pay 125% of the Permitted Completion Costs.

Permitted Completion Costs” means unpaid Project Costs (including Project Costs not included in the Construction Budget and Schedule delivered on the Closing Date) that the Borrower reasonably anticipates will be required for the Project Facilities to pay all remaining costs associated with outstanding Punch List Items (as defined in the Material Construction Contracts) work, retainage, fuel incentive payments, disputed amounts, start-up costs, bonuses and other costs required under the Material Construction Contracts.

Permitted Development Expenditures” means Development Expenditures that:

 

  (a)

are required by applicable law or regulations, any consent from a Governmental Authority, Industry Standards or Prudent Industry Practice applicable to the Development; or

 

  (b)

are otherwise used for the Development; and

are funded from (i) Equity Funding not otherwise committed to other expenditure for the Development, (ii) Insurance Proceeds and Condemnation Proceeds to the extent permitted by Article 5 (Insurance and Condemnation Proceeds and Performance Liquidated Damages) of the Common Security and Account Agreement or proceeds of dispositions to the extent permitted by Section 12.17 (Sale of Project Property) of the Common Terms Agreement or any equivalent provision of any other Senior Debt Instrument and (iii) Retained Excess Cash Flow, in the case of each of the foregoing sub-clauses (i), (ii) and (iii), in each case as expressly permitted under the Finance Documents and which use for the contemplated development could not reasonably be expected to have a Material Adverse Effect.

Permitted Finance Costs” means, for any period, the sum of all amounts of principal, interest, fees and other amounts payable in relation to Indebtedness (other than Senior Debt and other than LC Costs and other amounts payable in relation to Indebtedness that constitute Operation and Maintenance Expenses) permitted by Section 12.14(b) (Limitation on Indebtedness) (including guarantees thereof permitted under Section 12.15 (Guarantees) of the Common Terms Agreement during such period) plus all amounts payable during such period pursuant to Permitted Hedging Instruments that are not secured, plus any amounts

 

-206-

Calcasieu Pass - Common Terms Agreement


required to be deposited in margin accounts pursuant to Permitted Hedging Instruments; provided that Permitted Finance Costs will not include funds categorized as Operation and Maintenance Expenses under the last sentence of the definition thereof.

Permitted Finance Costs Reserve Account” is the account described in Section 4.3(a)(xiii) (Accounts) of the Common Security and Account Agreement.

Permitted Hedging Instrument” means (a) each Initial Permitted Senior Debt Hedging Instrument; or (b) a Hedging Instrument entered into by the Borrower in the ordinary course of business and that (i) is with a Hedging Bank or a Gas Hedge Provider, and (ii) is entered for non-speculative purposes and is on arm’s- length terms; provided that if such Hedging Instrument is a Gas Hedging Instrument, it is for a period not to exceed the three prompt month contracts (or in the case of Basis Swaps, thirty six months) and the aggregate quantum under all (1) Futures Contracts, Fixed-Floating Futures Swaps, NYMEX Natural Gas Futures Contracts and Swing Swaps does not exceed 50 TBtu, (2) Index Swaps does not exceed 23.25 TBtus, and (3) Basis Swaps does not exceed 23.25 TBtus, where the limitations in each of the categories described in sub-clauses (1), (2) and (3) are not aggregated. “Permitted Hedging Instrument” includes any “Permitted Senior Debt Hedging Instrument.” For the avoidance of doubt, each Anticipatory Hedge shall constitute (i) a Permitted Hedging Instrument and (ii) upon the relevant counterparty acceding to the Common Security and Account Agreement, a Permitted Senior Debt Hedging Instrument, in each case for all purposes hereunder and under the other Transaction Documents. As used in the preceding sentence, “Anticipatory Hedge” means any interest rate transaction between a Hedging Bank and Venture Global LNG, Inc. entered into prior to the Closing Date, and any Hedging Instrument entered into between a Hedging Bank and the Borrower, which results from an assignment, novation, participation, or any other conveyance or transfer of an Anticipatory Hedge (including any restructuring thereof or offsetting transactions related thereto) to the Borrower.

Permitted Hedging Liabilities” means all present and future liabilities (actual or contingent) payable or owing by an Obligor under Permitted Hedging Instruments (including the obligation to pay a Hedging Termination Amount) together with:

 

  (a)

any novation, deferral or extension of any of those liabilities;

 

  (b)

any claim for damages or restitution arising out of, by reference to or in connection with any of those liabilities;

 

  (c)

any claim flowing from any recovery by an Obligor or a receiver or liquidator thereof or any other Person of a payment or discharge in respect of any of those liabilities on grounds of preference or otherwise; and

 

-207-

Calcasieu Pass - Common Terms Agreement


  (d)

any amounts (such as post-insolvency interest) which could be included in any of the above but for any discharge, non-provability, unenforceability or non-allowability of the same in any insolvency or other proceedings.

Permitted Liens” means:

 

  (a)

Liens for taxes not delinquent or being contested in good faith and by appropriate proceedings in relation to which appropriate reserves are maintained and liens for customs duties that have been deferred in accordance with the laws of any applicable jurisdiction;

 

  (b)

deposits or pledges to secure obligations under workmen’s compensation, old age pensions, social security or similar laws or under unemployment insurance;

 

  (c)

deposits or other financial assurances to secure bids, tenders, contracts (other than for borrowed money), leases, concessions, licenses, statutory obligations, surety and appeal bonds (including any bonds permitted under the Material Construction Contracts), performance bonds and other obligations of like nature arising in the ordinary course of business and cash deposits incurred in connection with natural gas purchases;

 

  (d)

mechanics’, workmen’s, materialmen’s, suppliers’, warehouse, Liens of lessors and sublessors or other like Liens arising or created in the ordinary course of business with respect to obligations that are not due or that are being contested in good faith;

 

  (e)

servitudes, easements, rights of way, encroachments and other similar encumbrances burdening the Project Facilities’ land that are granted in the ordinary course, imperfections of title on real property, and restrictive covenants, zoning restrictions, licenses or conditions on the grant of real property (in relation to such real property); provided that such servitudes, easements, rights of way, encroachments and other similar encumbrances, imperfections, restrictive covenants, restrictions, licenses or conditions do not materially interfere with the Development as contemplated in the Finance Documents and the Material Project Agreements or have a material adverse effect on the Security Interests;

 

  (f)

Liens to secure Indebtedness permitted by Sections 12.14(h) and (p) (Limitation on Indebtedness) of the Common Terms Agreement;

 

  (g)

the Security Interests;

 

  (h)

Liens in the ordinary course of business arising from or created by operation of applicable law or required in order to comply with any applicable law and that could not reasonably be expected to cause a Material Adverse Effect or materially impair the Development’s use of the encumbered assets;

 

-208-

Calcasieu Pass - Common Terms Agreement


  (i)

Liens in the ordinary course of business over any assets (the aggregate value of which assets at the time any such Lien is granted does not exceed $25 million) that could not reasonably be expected to cause a Material Adverse Effect or materially impair the Development’s use of the encumbered assets;

 

  (j)

contractual or statutory rights of set-off (including netting) granted to the Obligors’ bankers, under any Permitted Hedging Instrument or any Material Project Agreement and that could not reasonably be expected to cause a Material Adverse Effect;

 

  (k)

deposits or other financial assurances to secure reimbursement or indemnification obligations in respect of letters of credit or in respect of letters of credit put in place by an Obligor and payable to suppliers, service providers, insurers or landlords in the ordinary course of business;

 

  (l)

Liens that are scheduled exceptions to the coverage afforded by a Title Policy on the Closing Date or later date of amendment of a Title Policy or delivery of a new Title Policy;

 

  (m)

legal or equitable encumbrances (other than any attachment prior to judgment, judgment lien or attachment in aid of execution on a judgment) deemed to exist by reason of the existence of any pending litigation or other legal proceeding if the same is effectively stayed or the claims secured thereby are being contested in good faith and by appropriate proceedings and an appropriate reserve has been established in respect thereof in accordance with GAAP;

 

  (n)

the Liens created pursuant to the Real Property Documents;

 

  (o)

Liens created by any fee owner under a Lease, to the extent permitted by such Lease;

 

  (p)

Liens by any Obligor in favor of any other Obligor; and

 

  (q)

Liens arising out of judgments or awards not constituting an Event of Default so long as an appeal or proceeding for review is being prosecuted in good faith and for the payment of which adequate cash reserves, bonds or other cash equivalent security have been provided or are fully covered by insurance (other than any customary deductible).

Permitted Payments” means, without duplication as to amounts allowed to be distributed under any other provision of the Common Terms Agreement:

 

-209-

Calcasieu Pass - Common Terms Agreement


  (a)

payments to an Affiliate of the Borrower to permit such Affiliate to pay its reasonable accounting, legal and administrative expenses when due, in an aggregate amount not to exceed $5 million per calendar year (escalating annually in accordance with the applicable Material Project Documents); and

 

  (b)

(i) with respect to any periods (or portions thereof) ending before the Project Completion Date, the amount necessary for payment to an Affiliate of the Borrower to enable it (or, if such Affiliate is a flow- through entity for U.S. federal income tax purposes, its beneficial owners) to pay its (or such beneficial owners’) income tax liability with respect to income generated by the Obligors as a result of sales pursuant to the LNG SPAs for any periods (or portions thereof) ending prior to the Project Completion Date and (ii) with respect to any periods (or portions thereof) ending after the Project Completion Date, the amount necessary for payment to an Affiliate of the Borrower to enable it (or, if such Affiliate is a flow-through entity for U.S. federal income tax purposes, its beneficial owners) to pay its (or such beneficial owners’) income tax liability with respect to income generated by the Obligors, provided that such income tax liability shall be determined hypothetically based on the aggregate net taxable income of the Obligors and the highest combined tax rate applicable to an individual residing in New York, New York for the applicable period.

Permitted Senior Debt Hedging Instrument” means a Permitted Hedging Instrument in respect of which the Hedging Banks has acceded to the Common Security and Account Agreement.

Permitted Senior Debt Hedging Liabilities” means all present and future liabilities (actual or contingent) payable or owing by a Obligor under Permitted Senior Debt Hedging Instruments (including the obligation to pay a Senior Debt Hedging Termination Amount) together with:

 

  (a)

any novation, deferral or extension of any of those liabilities;

 

  (b)

any claim for damages or restitution arising out of, by reference to or in connection with any of those liabilities;

 

  (c)

any claim flowing from any recovery by a Obligor or a receiver or liquidator thereof or any other Person of a payment or discharge in respect of any of those liabilities on grounds of preference or otherwise; and

 

  (d)

any amounts (such as post-insolvency interest) which would be included in any of the above but for any discharge, non-provability, unenforceability or non-allowability of the same in any insolvency or other proceedings.

 

-210-

Calcasieu Pass - Common Terms Agreement


Person” means any individual, firm, corporation, partnership, joint venture, association, trust, unincorporated organization, Governmental Authority or other entity whether enjoying legal personality or not, and includes its successors or permitted assignees.

PGNIG” means Polskie Górnictwo Naftowe I Gazownictwo Spółka Akcyjna.

Pipeline Construction Contract” means the Pipeline Construction Agreement, dated as of January 23, 2019, by and between the Guarantor and the Pipeline Contractor, as amended by Change Order No. 1, dated as of June 13, 2019, Change Order No. 2, dated as of June 14, 2019, Amendment No. 1 to Pipeline Construction Agreement, dated as of June 28, 2019, and Change Order No. 3, dated as of July 19, 2019, and supplemented by LNTP No. 1, dated as of January 24, 2019, LNTP No. 2, dated as of January 25, 2019, and Full Notice to Proceed, dated as of June 28, 2019, in each case, by and between the Guarantor and the Pipeline Contractor.

Pipeline Contractor” means WHC, LLC.

Pipeline Service Agreements” means:

 

  (a)

the Firm Transportation Service Agreement, dated as of July 10, 2019, by and between the Guarantor and the Borrower; and

 

  (b)

the Interruptible Transportation Service Agreement, dated as of July 10, 2019, by and between the Guarantor and the Borrower.

PIS Purchase Order” means that certain Purchase Order Contract for the Sale of Power Island System, dated as of September 25, 2018, by and between the Borrower and BHGE, as supplemented by Limited Notice to Proceed, dated as of February 5, 2019 and that letter agreement, dated June 24, 2019, by and between the Borrower and BHGE, and as amended by Change Order No. 1, dated as of June 24, 2019, by and between the Borrower and BHGE.

Plan” means any “employee benefit plan” as defined in Section 3(3) of ERISA, including any “employee welfare benefit plan” (as defined in Section 3(1) of ERISA) and/or any “employee pension benefit plan” (as defined in Section 3(2) of ERISA), that is or was maintained or contributed to by any Obligor or any ERISA Affiliate.

Pledge Agreement” has the meaning given in Section 3.3 (Security Interests to be Granted by Pledgor) of the Common Security and Account Agreement.

Pledged Collateral” has the meaning given in Section 3.2(a) (Security Interests to be Granted by the Obligors – Pledge of Pledged Collateral) of the Common Security and Account Agreement.

 

-211-

Calcasieu Pass - Common Terms Agreement


Pledged Debt Securities” has the meaning given in Section 3.2(a)(vii) (Security Interests to be Granted by the Obligors – Pledge of Pledged Collateral) of the Common Security and Account Agreement.

Pledged Equity Interests” has the meaning given in Section 3.2(a)(i) (Security Interests to be Granted by the Obligors – Pledge of Pledged Collateral) of the Common Security and Account Agreement.

Pledgor” means Calcasieu Pass Pledgor, LLC, a limited liability company organized under the laws of the State of Delaware.

Pre-Completion Revenues Account” is the account described in Section 4.3(a)(iii) (Accounts) of the Common Security and Account Agreement.

Pretreatment Contract” means that certain Engineering and Procurement Agreement relating to the pre-treatment system for the Calcasieu Pass LNG export and liquefaction facility in Cameron Parish, Louisiana, dated as of December 21, 2018, by and between the Borrower and UOP, as amended by Amendment No. 1 to Engineering and Procurement Agreement, dated as of June 28, 2019, and Amendment No. 2 to Engineering and Procurement Agreement, dated as of August 16, 2019, and supplemented by Limited Notice to Proceed, dated as of December 21, 2018, and Limited Notice to Proceed No. 2, dated as of June 28, 2019, by and between the Borrower and UOP, together with that certain Amended and Restated Natural Gas Integrated Pretreatment Block License Agreement, dated as of July 17, 2019, by and between the Borrower and UOP.

Pro Rata Payment” means, in respect of the Senior Debt Obligations, a payment to a Senior Creditor on any date on which a payment of Senior Debt Obligations is made in which:

 

  (a)

the amount of interest paid to such Senior Creditor on such date bears the same proportion to the total amount of interest payments made to all Senior Creditors on such date as (i) the total amount of Senior Debt Obligations for interest due to such Senior Creditor on such date bears to (ii) the total amount of Senior Debt Obligations for interest due to all Senior Creditors on such date;

 

  (b)

the amount of principal paid to such Senior Creditor on such date bears the same proportion to the total amount of principal payments made to all Senior Creditors on such date as (i) the total amount of Senior Debt Obligations for principal due to such Senior Creditor on such date bears to (ii) the total amount of Senior Debt Obligations for principal due to all Senior Creditors on such date, in each case not including any principal payable by way of an acceleration of principal unless each Senior Debt Obligation has been accelerated; and

 

-212-

Calcasieu Pass - Common Terms Agreement


  (c)

fees, commissions, indemnities and all amounts other than interest and principal paid to such Senior Creditor on such date bears the same proportion to the total fees, commissions, indemnities and such other amounts paid to all Senior Creditors on such date as (i) the total Senior Debt Obligations for fees, commissions, indemnities and such other amounts due to such Senior Creditor on such date bears to (ii) the total Senior Debt Obligations for fees, commissions, indemnities and such other amounts due to all Senior Creditors on such date.

If payments cannot be made exactly in such proportion due to minimum required payment amounts and required integral multiples of payments under Senior Debt Instruments, payments made in amounts as near such exactly proportionate amounts as possible shall be deemed to be Pro Rata Payments.

Project Completion Date” means the date upon which all of the conditions set forth in Section 14.1 (Conditions to Occurrence of the Project Completion Date) of the Common Terms Agreement have been either satisfied, or, in each case, waived by the Requisite Intercreditor Parties.

Project Completion Date Distribution” means an amount equal to the sum of (a) 25% of the amount remaining on deposit in the Contingency Reserve Account after giving effect to the application of clauses (ii)(A) through (ii)(D) of Section 14.2(c) (Project Completion Date Waterfall) and the amounts available for distribution pursuant to clause (b) of this definition, plus (b) 100% of any Cash Flows of the Obligors received prior to the Project Completion Date that are deposited into the Pre-Completion Revenues Account.

Project Costs” means all costs of acquiring, leasing, designing, engineering, developing, permitting, insuring, financing (including closing costs, other fees and expenses, commissions and discounts payable to any purchaser or underwriter of Senior Notes (to the extent such costs are paid from the proceeds of such Senior Notes), insurance costs (including premiums) and interest during construction and interest rate hedge expenses and Secured Party Fees during construction), constructing, installing, commissioning, testing and starting-up (including costs relating to all equipment, materials, spare parts and labor for) the Project Facilities, funding the Senior Facilities Debt Service Reserve Account and the Contingency Reserve Account and all other costs incurred with respect to the Development in accordance with the Construction Budget and Schedule, including working capital prior to the end of the Term Loan Availability Period (on terms set forth for the Working Capital Facility in the Credit Facility Agreement), gas purchase, transport and storage costs and Operation and Maintenance Expenses, in each case incurred prior to the Project Completion Date, and/or reimbursement of Drawstop Equity Contributions solely to the extent the proceeds of such Drawstop Equity Contributions have been used to pay Project Costs and after satisfaction of the conditions set forth in Section 4.2 (Conditions to Each Advance). On any date on which a determination is being

 

-213-

Calcasieu Pass - Common Terms Agreement


made whether specific sources of funding available to the Obligors are sufficient for the Development to achieve the Project Completion Date by the Date Certain, the Project Costs against which the applicable sources of funding are measured to make this determination will be the remaining Project Costs required to be spent in order to achieve the Project Completion Date as determined as of such determination date based on the then-current Construction Budget and Schedule, including in the case of commissioning costs determined on a net basis consistent with the then-current Construction Budget and Schedule.

Project Facilities” means the LNG Facility and the TransCameron Pipeline, as such facilities may be repaired and replaced from time to time or modified, changed or expanded as permitted in the Finance Documents.

Project Property” means, at any point in time, all Project Facilities, material Permits in respect of the Development, information, data, results (technical, economic, business or otherwise) known and other information that was developed or acquired as a result of Development operations.

Prudent Industry Practice” means, at a particular time, any of the practices, methods, standards and procedures (including those engaged in or approved by a material portion of the LNG industry) that, at that time, in the exercise of reasonable judgment in light of the facts known at the time a decision was made, could reasonably have been expected to accomplish the desired result consistent with good business practices, including due consideration of the Development’s reliability, environmental compliance, economy, safety and expedition, and which practices, methods, standards and acts generally conform to International LNG Terminal Standards and International LNG Vessel Standards, and solely with respect to Section 12.27 (Gas Transportation Arrangements; Gas Purchase Arrangements) of the Common Terms Agreement and the definition of “Qualified Gas Supplier”, the standard industry practice applicable to the gas supply industry, including providing due consideration of the need for reliable supply and taking into account the credit quality, track record and experience of suppliers, diversity of supply sources, quality of gas supplied and prudent contracting strategy in order to enable the Development to receive the quantum of natural gas required from time to time to meet the obligations of the Obligors under the LNG SPAs.

PUHCA” means the Public Utility Holding Company Act of 2005 and FERC’s implementing regulations.

Qualified ECP Party” means, in respect of any Swap Obligation, each Obligor that has total assets exceeding $10 million at the time the relevant guaranty or grant of the relevant security interest becomes effective with respect to such Swap Obligation or such other person as constitutes an “eligible contract participant” under the Commodity Exchange Act or any regulations promulgated thereunder and can cause another person to qualify as an “eligible contract participant” at such time by entering into a keepwell under Section 1a(18)(A)(v)(II) of the Commodity Exchange Act.

 

-214-

Calcasieu Pass - Common Terms Agreement


Qualified Gas Supplier” means suppliers of Gas reasonably selected from time to time by the Borrower in accordance with Prudent Industry Practice, including the suppliers listed on Exhibit A to the Gas Sourcing Plan, as updated semi- annually.

Qualified Operator” means any Person that, directly or indirectly through an affiliate, within the last five (5) years, (a) is engaged in the business of procuring or transporting at least 1.0 Bcf of natural gas per day, (b) has operated LNG liquefaction facilities processing not less than 4.5 MTPA of LNG and (c) is in compliance with the requirements of the USA Patriot Act (including applicable, and uniformly applied, “know your customer” regulations) and all other applicable Anti-Terrorism and Money Laundering Laws and satisfies applicable “know your customer” requirements of the Facility Lenders.

Qualified Owner” means any Person that, directly or through an affiliate, (a) either (i) is (or is a Subsidiary or a controlled affiliate of) a Qualified Operator, (ii) has engaged a Qualified Operator to operate the Project Facilities, (iii) has engaged with one or more Affiliates of Venture Global LNG, Inc. to operate the Project Facilities or (iv) has provided the Intercreditor Agent with a certificate from the Independent Engineer stating that such Person (or its designated operator) is qualified to operate the Project Facilities, (b) either (i) has an Investment Grade rating or (ii) is a person that has a tangible net worth or assets of at least $10 billion; provided that any Qualified Owner shall satisfy applicable “know your customer” requirements of the Facility Lenders and (c) is in compliance with the requirements of the USA Patriot Act (including applicable, and uniformly applied, “know your customer” regulations) and all other applicable Anti-Terrorism and Money Laundering Laws.

Qualified Transporter” means any Person possessing the requisite FERC permit or requisite Louisiana Public Service Commission authorization to transport Gas.

Qualifying LNG SPA” has the meaning given in Section 8.1(b) (LNG SPA Maintenance) of the Common Terms Agreement.

Qualifying Term” means (a) with respect to any new LNG SPA that meets the conditions to be, or is approved as, a Qualifying LNG SPA, the term of such LNG SPA is no shorter than the amortization term of the Initial Senior Debt or (b) with respect to any LNG SPA replacing a Qualifying LNG SPA, a term at least as long as the remaining term of the Qualifying LNG SPA it is replacing.

Quarterly Payment Date” means each March 31, June 30, September 30 and December 31.

 

-215-

Calcasieu Pass - Common Terms Agreement


Real Estate” means all land, together with the buildings, structures, parking areas, and other improvements thereon, now or hereafter owned by an Obligor, including all easements, rights-of-way, servitudes and similar rights relating thereto and all leases and tenancies, and all rights of occupancy thereof of a nature comparable to a lease.

Real Property Documents” means, at any time, (i) the documents evidencing the Real Estate owned (or leased) by the Obligors and (ii) the documents evidencing the Real Estate in which a license or servitude has been granted to an Obligor (including, for the avoidance of doubt for purposes of this clause (ii), documents evidencing Real Estate on which the TransCameron Pipeline is or is to be situated). As of the Closing Date, such documents referenced in clause (i) are set forth on Schedule U (Real Property Documents) to the Common Terms Agreement.

Reasonable Commercial Terms” has the meaning given in Section 12.28(a) (Insurance Covenant) of the Common Terms Agreement.

Receiver” means an administrator, a receiver or receiver and manager, or, where permitted by law, an administrative receiver or equivalent officer or person in a relevant jurisdiction of the whole or any part of the Collateral.

Register” has the meaning given in Section 19.7 (Register) of the Common Terms Agreement.

Related Parties” means, with respect to any specified Person, such Person’s Affiliates and the respective shareholders, members, partners, directors, officers, employees, agents, trustees, advisors and representatives of such Person and such Person’s Affiliates.

Release” means, with respect to any Hazardous Material, any release, spill, emission, leaking, pouring, emptying, escaping, dumping, pumping, injection, deposit, disposal, discharge, dispersal, leaching or migration of such Hazardous Material into the environment, including the movement of such Hazardous Material through ambient air, soil, surface water, ground water, wetlands, land or subsurface strata.

Relevant Interest Period” means, with respect to each Loan, the “Interest Period” and/or “Interest Payment Period”, as applicable, as defined in the relevant Facility Agreement.

Repeated Representations” means the representations and warranties described in Section 5.2 (Repeated Representations and Warranties of the Obligors) of the Common Terms Agreement.

 

-216-

Calcasieu Pass - Common Terms Agreement


Replacement Facility Agent Accession Agreement” has the meaning given in Section 19.3(b)(ii) (Replacement of Facility Agents) of the Common Terms Agreement.

Replacement Material Contract” means any agreement entered into in replacement of a Material Project Agreement (a) which has substantially similar or more favorable economic effect for Borrower or the Guarantor, as applicable, when taken as a whole together with any other agreements related thereto and (b) which has substantially similar or more favorable non-economic terms (taken as a whole) for Borrower or the Guarantor, as applicable, as the Material Project Agreement being replaced.

Replacement Senior Debt” has the meaning given in Section 6.3(a) (Replacement Senior Debt) of the Common Terms Agreement.

Repsol” means Repsol LNG Holding, S.A.

Required Capital Expenditures” means capital expenditures required to meet the requirements of any applicable laws and regulations, Permits (or interpretations thereof), or insurance policies, Industry Standards, and Prudent Industry Practice with which the Obligors are obligated to comply under any Material Project Agreement and any other material agreements of the Obligors relating to the Development, including those relating to the environment.

Required Export Authorization” means, with respect to a Qualifying LNG SPA at any time, (a) the Non-FTA Authorization and (b) the FTA Authorization to the extent that (i) at such time, the volumes permitted to be exported under the FTA Authorization or the Non-FTA Authorization, as the case may be, are required in order to enable the sale of such Qualifying LNG SPA’s share of the then- applicable Base Committed Quantity of LNG in accordance with the terms of such Qualifying LNG SPA and (ii) an objection has not been received in respect of the identification of such Export Authorization as being (or not being) a “Required Export Authorization” pursuant to Section 8.1(b)(iv) (LNG SPA Maintenance) of the Common Terms Agreement. For the avoidance of doubt, the Non-FTA Authorization is a Required Export Authorization for each of the Initial LNG SPAs in effect on the Closing Date and until otherwise determined in accordance with Section 8.2(a)(ii) (LNG SPA Mandatory Prepayment) of the Common Terms Agreement.

Required Intercreditor Parties” has the meaning given in Section 1.1 (Definitions) of the Intercreditor Agreement.

Required LNG SPA” means, at any time, the Qualifying LNG SPAs required to be maintained pursuant to Section 8.1(a) (LNG SPA Covenants – LNG SPA Maintenance) of the Common Terms Agreement at such time.

 

-217-

Calcasieu Pass - Common Terms Agreement


Requisite Intercreditor Parties” has the meaning given in Section 1.1 (Definitions) of the Intercreditor Agreement.

Reservations” means the principle that equitable remedies are remedies which may be granted or refused at the discretion of the court, the limitation of enforcement by laws relating to bankruptcy, insolvency, liquidation, re- organization, court schemes, moratorium, administration and other laws generally affecting the rights of creditors, the time barring of claims under any legislation relating to limitation of claims, the possibility that an undertaking to assume liability for or to indemnify a Person against non-payment of stamp duty may be void, defenses of set-off or counterclaim and similar principles, in each case both under New York law and the laws of other applicable jurisdictions and such other qualifications as to matters of law as are contained in the legal opinions provided to the Senior Creditors pursuant to Section 4.1 (Conditions to Closing Date and Initial Advance) of the Common Terms Agreement.

Restricted Document” has the meaning given in Section 12.6(c) (Confidentiality) of the Common Security and Account Agreement.

Restricted Payment” means (a) any dividend or other distribution by the Borrower (in cash, property of the Borrower, securities, obligations, or other property) on, or other dividends or distributions on account of, or the setting apart of money for a sinking or other analogous fund for, or the purchase, redemption, retirement or other acquisition by the Borrower of, any portion of any membership interest in the Borrower and (b) all payments (in cash, property of the Borrower, securities, obligations, or other property) of principal of, interest on and other amounts with respect to, or other payments on account of, or the setting apart of money for a sinking or other analogous fund for, or the purchase, redemption, retirement or other acquisition by the Borrower of, any Indebtedness owed to Pledgor or any other Person party to a pledge agreement or any Affiliate thereof, including any Subordinated Debt. Restricted Payments shall not include (i) payments under the Service Agreements (which shall be paid in accordance with Section 4.7 (Cash Waterfall) of the Common Security and Account Agreement), (ii) Permitted Payments (which shall be paid in accordance with Sections 4.5(b)(ii)(C) (Deposits and Withdrawals – Pre-Completion Revenues Account) and/or 4.7 (Cash Waterfall) of the Common Security and Account Agreement) and (iii) any of the payments in (a) or (b) above (whether in cash, securities, obligations or otherwise) made among any of the Obligors.

Retained Excess Cash Flow” means, as of any date of determination, amounts on deposit in the Equity Proceeds Account that are available to be utilized for the making of a Restricted Payment under Section 11.1 (Conditions to Restricted Payments) of the Common Terms Agreement which, instead of being utilized to make a Restricted Payment, are retained by the Borrower and used for other purposes contemplated by the Financing Documentation.

 

-218-

Calcasieu Pass - Common Terms Agreement


Revenue Account” is the account described in Section 4.3(a)(v) (Accounts) of the Common Security and Account Agreement.

Rolling Stock” means any motor vehicles, tractors, trailers and other like property, whether or not the title thereto is governed by a certificate of title or ownership and other rolling stock, including such property for which the title thereto is evidenced by a certificate of title issued by the United States or a state that permits or requires a lien thereon to be evidenced upon such title.

S&P” means Standard & Poor’s Ratings Services, a division of McGraw-Hill Financial, Inc., or any successor thereto.

Sanctions” means any financial sanctions or economic or trade embargoes administered or enforced from time to time by the U.S. Department of State or the U.S. Department of Treasury (including the Office of Foreign Assets Control), or any other applicable U.S. sanctions authority (including OFAC Laws), the United Nations Security Council, the European Union, any EU member state or Her Majesty’s Treasury.

Sanctioned Person” has the meaning given in Section 5.1(h)(iv) (Sanctions, Anti- Corruption Laws and USA Patriot Act) of the Common Terms Agreement.

Sanctions Violation” has the meaning given in Section 12.6(d) (Compliance with Law) of the Common Terms Agreement.

Schedule Bonus” means the bonus for early completion as described in Section 9.5 of the Pipeline Construction Contract and/or the delivery bonus as described in Section 6.7 of the LTS Purchase Order, as applicable

Schedule of Minimum Insurance” has the meaning given in Section 12.28(a) (Insurance Covenant) of the Common Terms Agreement.

Secured Accounts” means the Accounts, excluding the Excluded Unsecured Accounts.

Secured Parties” means the Senior Creditors, the Senior Creditor Group Representatives, the Intercreditor Agent, the Collateral Agent and the Account Bank.

Secured Party Fees” means any fees, costs, indemnities, charges, disbursements, liabilities and expenses (including reasonably incurred legal fees and expenses) and all other amounts payable to the Collateral Agent, the Intercreditor Agent, the Indenture Trustee or the Account Bank, as applicable, or any of their respective agents and to any Senior Creditor Group Representative.

Securities Act” means the Securities Act of 1933.

 

-219-

Calcasieu Pass - Common Terms Agreement


Security Documents” means the Common Security and Account Agreement and any other document, agreement, notice, mortgage, instrument or filing creating and/or perfecting any Lien required to be created or perfected by the Common Security and Account Agreement or any other Finance Document and shall include the Pledge Agreement, any deed of trust or mortgage entered into pursuant to Section 3.2(f) (Security Interests to be Granted by the Obligors Real Property) of the Common Security and Account Agreement, including the Mortgage, any Patent or Trademark security agreement entered into pursuant to Section 3.5(g) (Perfection and Maintenance of Security Interest Intellectual Property Recording Requirements) of the Common Security and Account Agreement, and any account control agreement (including the Control Agreements) entered into pursuant to Section 4.12(a) (Local Accounts) of the Common Security and Account Agreement.

Security Enforcement Action” means the exercise by the Collateral Agent (or at its direction), following initiation of enforcement action in compliance with Section 6.2 (Initiation of Security Enforcement Action) and Section 6.3 (Conduct of Security Enforcement Action) of the Common Security and Account Agreement, of enforcement rights with respect to the Collateral and any of the other enforcement rights (including exercising step-in and other rights with respect to the Direct Agreements entered into pursuant to Section 3.4 (Direct Agreements) of the Common Security and Account Agreement) contemplated by the Common Security and Account Agreement, the other Security Documents and the Direct Agreements. For the avoidance of doubt, Security Enforcement Action shall not include any action taken by the Collateral Agent (or at its direction) in accordance with Section 6.1 (Collateral Agent Action Generally) of the Common Security and Account Agreement.

Security Enforcement Action Initiation Request” has the meaning given in Section 6.2(a) (Initiation of Security Enforcement Action) of the Common Security and Account Agreement.

Security Enforcement Action Representative” means, at any time, a Senior Creditor Group Representative, or a group of Senior Creditor Group Representatives acting together, that represents a Majority in Interest of the Senior Creditors (for purposes of this definition only, the “Majority Representative”); provided that:

 

  (a)

for so long as at least 20% of the outstanding principal amount of the Senior Debt Obligations is held by Facility Lenders, the Security Enforcement Action Representative shall be a Senior Creditor Group Representative, or a group of Senior Creditor Group Representatives acting together, that represents a Majority in Interest of the Senior Creditors which includes Facility Lenders holding a majority of the outstanding principal amount of the Senior Debt Obligations held by Facility Lenders;

 

-220-

Calcasieu Pass - Common Terms Agreement


  (b)

if there is no principal amount of Senior Debt Obligations then outstanding and at least 20% of the aggregate Senior Debt Commitments are held by Facility Lenders, the Security Enforcement Action Representative shall be a Senior Creditor Group Representative, or a group of Senior Creditor Group Representatives acting together, that represents a Majority in Interest of the Senior Creditors which includes Facility Lenders holding a majority of the aggregate Senior Debt Commitments held by Facility Lenders; and

 

  (c)

the Initiating Percentage shall be deemed to be the Security Enforcement Action Representative if and only for so long as the Majority Representative (or the Security Enforcement Action Representative as determined pursuant to clause (a) or (b) above) is not diligently pursuing a Security Enforcement Action unless stayed or otherwise precluded from doing so by law, regulation or order, in which case the Majority Representative (or the Security Enforcement Action Representative as determined pursuant to clause (a) or (b) above) shall remain the Security Enforcement Action Representative until the Majority Representative (or the Security Enforcement Action Representative as determined pursuant to clause (a) or (b) above) is no longer stayed or otherwise precluded from diligently pursuing a Security Enforcement Action and is nonetheless not diligently pursuing such Security Enforcement Action.

Security Interests” means the Liens created or purported to be created by or pursuant to the Security Documents.

Senior Creditor” means a provider of Senior Debt that benefits from the Common Security and Account Agreement, including the Facility Lenders, any Senior Noteholders and each Hedging Bank that is party to, or accedes to, the Common Security and Account Agreement.

Senior Creditor Group” means, at any one time, the following, each of which will constitute a separate Senior Creditor Group:

 

  (a)

the Credit Facility Lender Parties under the Credit Facility Agreement;

 

  (b)

the Facility Lenders (collectively) under any subsequent Facility Agreement;

 

  (c)

the Senior Noteholders (collectively) under any Indenture;

 

  (d)

each Hedging Bank; and

 

  (e)

any Senior Creditor or group of Senior Creditors, as the case may be, that provides Additional Senior Debt pursuant to a single Senior Debt Instrument entered into after the date of the Common Security and Account Agreement.

 

-221-

Calcasieu Pass - Common Terms Agreement


Senior Creditor Group Representative” means, with respect to any Senior Creditor Group, the representative of such Senior Creditor Group or the incumbent replacement thereof duly appointed as provided in Section 2.4 (Senior Creditor Group Representatives; Replacement or Appointment of Senior Creditor Group Representative) of the Common Security and Account Agreement; provided that, in the case of Hedging Banks acting in the capacity as a Senior Creditor Group Representative, such Hedging Bank shall only be entitled to act in such capacity in accordance with Section 7.3 (Hedging Banks) of the Common Security and Account Agreement. Each Facility Agent shall at all times be the Senior Creditor Group Representative for the relevant Senior Creditor Group and each Indenture Trustee shall at all times be the Senior Creditor Group Representative for the relevant Senior Noteholders.

Senior Debt” means the Initial Senior Debt, the Working Capital Debt and Senior Notes under the applicable Senior Debt Instrument existing on the Closing Date, any other permitted Additional Senior Debt (including such as may be incurred under any Senior Notes, or any other Senior Debt Instrument), obligations arising under the Permitted Senior Debt Hedging Instruments, any Additional Working Capital Debt and any Replacement Senior Debt, in each case benefiting from the Security Interests created under and pursuant to the Common Security and Account Agreement and incurred from time to time as permitted by the Finance Documents.

Senior Debt Commitments” means the aggregate principal amount any Senior Creditor is committed to disburse to the Borrower under any Senior Debt Instrument.

Senior Debt/Equity Ratio” means, as of the date of measurement, the ratio of (a) the sum of principal amounts of Senior Debt (excluding any Letters of Credit and unfunded Senior Debt Commitments, but including any Working Capital Loans and any LC Reimbursement Payments) incurred as of such date or Senior Debt or Senior Debt Commitments projected to be incurred and funded under the Base Case Forecast as of such date, as applicable, to (b) the aggregate amount of Equity Funding applied as of such date towards Project Costs or contributed to the Borrower or the Guarantor and on deposit in a Secured Account (including any Cash Flow from operations prior to the Project Completion Date applied towards Project Costs) or Cash Flow from operations projected as of such date to be applied towards Project Costs under the Base Case Forecast (including Equity Funding constituting Cash Flow that is reasonably expected to be received by the Obligors on or prior to the Project Completion Date), as applicable.

Senior Debt Hedging Termination Amount” means any Permitted Senior Debt Hedging Liability due as a result of the termination of a Permitted Senior Debt Hedging Instrument and/or the termination of any transaction entered into thereunder.

Senior Debt Instrument” means:

 

-222-

Calcasieu Pass - Common Terms Agreement


  (a)

each Facility Agreement, including with respect to each Facility Agreement, the Common Terms Agreement;

 

  (b)

any Indenture and any Senior Notes issued pursuant to such Indenture; and

 

  (c)

any credit agreement, indenture, trust deed, note or other instrument pursuant to which the Borrower incurs permitted Additional Senior Debt from time to time.

For the avoidance of doubt, the term “Senior Debt Instrument” shall not include any Permitted Hedging Instrument (including, for the avoidance of doubt, any Permitted Senior Debt Hedging Instrument).

Senior Debt Obligations” means the obligations of the Borrower and the obligations of the Guarantor under its guarantee granted under and pursuant to the Common Security and Account Agreement in each case to pay:

 

  (a)

all principal, interest and premiums on the disbursed Senior Debt;

 

  (b)

all commissions, fees, reimbursements, indemnities, prepayment premiums and other amounts payable to Senior Creditors under any Senior Debt Instrument;

 

  (c)

all Permitted Senior Debt Hedging Liabilities under Permitted Hedging Instruments in respect of which the Hedging bank has acceded to the Common Security and Account Agreement; and

 

  (d)

all Secured Party Fees;

in each case whether such obligations are present, future, actual or contingent and including the payment of amounts that would become due under the Senior Debt Instruments or the Permitted Senior Debt Hedging Instruments but for the operation of the automatic stay under Section 362(a) of the Bankruptcy Code.

Senior Facilities Debt Service Reserve Account” is the account described in Section 4.3(a)(viii) (Accounts) of the Common Security and Account Agreement.

Senior Facilities Reserve Amount” means as of any date on and after the Project Completion Date, an amount necessary to pay Facility Debt Obligations projected to be due and payable on the next two (2) (in the case of quarterly Payment Dates) or one (1) (in the case of semi-annual Payment Dates) Payment Dates (assuming that no Event of Default will occur during such period) taking into account, with respect to interest, the amount of interest that would accrue on the aggregate principal amount of Facility Debt Obligations outstanding for the covered six month period and only such interest amount after giving effect to any Permitted Hedging Instrument in respect of interest rates then in effect; provided that (a) the Facility Debt Obligations projected to be due and payable for purposes of this

 

-223-

Calcasieu Pass - Common Terms Agreement


calculation shall not include (i) Working Capital Debt; (ii) any voluntary or mandatory prepayment; or (iii) Hedging Termination Amounts; and (b) for purposes of the calculation of the scheduled principal payments in respect of any Senior Debt, any final balloon payment in respect of such Senior Debt shall not be taken into account and instead only the equivalent of the principal payment on the immediately preceding Payment Date for payment of principal prior to such balloon payment shall be taken into account.

Senior Note Disbursement Accounts” has the meaning given in Section 4.3(a)(ii) (Accounts) of the Common Security and Account Agreement.

Senior Noteholder” means any holder of Senior Notes (or lenders in the case of a “term loan B” financing that the Borrower has elected to be treated as an Indenture).

Senior Notes” means the notes to be issued (or facility agreement to be entered into in the case of a “term loan B” financing that the Borrower has elected to be treated as an Indenture) pursuant to any Indenture.

Service Agreements” means:

 

  (a)

the Operation and Maintenance Agreement relating to the LNG Export and Liquefaction Facility to be located at the Calcasieu Pass Site in Cameron Parish, Louisiana, dated as of August 9, 2019, by and between the Borrower and Calcasieu Pass Operations, LLC;

 

  (b)

the Administrative Services Agreement relating to the LNG Export and Liquefaction Facility to be located at the Calcasieu Pass Site in Cameron Parish, Louisiana, dated as of July 9, 2019, by and between the Borrower and Venture Global Services, LLC;

 

  (c)

the Pipeline Operation and Maintenance Agreement relating to the TransCameron Natural Gas Pipeline dated as of August 9, 2019, by and between the Guarantor and TransCameron Operations, LLC;

 

  (d)

the Administrative Services Agreement relating to the TransCameron Natural Gas Pipeline, dated as of July 9, 2019, by and between the Guarantor and Venture Global Services, LLC;

 

  (e)

the long-term service agreement to be entered into by and between the Borrower and BHGE;

 

  (f)

the Field Services Agreement, dated as of August 14, 2019, by and between the Borrower and BHGE; and

 

  (g)

the Technical Advisor Services Agreement, dated as of July 29, 2019, by and between the Borrower and UOP.

 

-224-

Calcasieu Pass - Common Terms Agreement


Shell” means Shell NA LNG LLC.

SIGTTO” has the meaning given in this Section 1.3 of Schedule A (Common Definitions and Rules of Interpretation Definitions) within the definition of International LNG Terminal Standards.

Site” means, collectively, each parcel or tract of land upon which any portion of the Project Facilities are or will be located.

Solvent” means, with respect to any Person as of the date of any determination, that on such date:

 

  (a)

the fair valuation of the assets of such Person, on a consolidated basis, is greater than the liabilities of such Person on a consolidated basis, including, without limitation, contingent liabilities;

 

  (b)

the present fair saleable value of the assets of such Person, on a consolidated basis, is at least the amount that will be required to pay the probable liability, on a consolidated basis, of such Person on its debts as they become absolute and matured;

 

  (c)

such Person is able to pay its debts and other liabilities, contingent obligations, and other commitments as they become absolute and matured in the normal course of business; and

 

  (d)

such Person is not engaged in business or a transaction, and is not about to engage in business or a transaction, for which such Person’s assets would constitute unreasonably small capital after giving due consideration to current and anticipated future business conduct.

In computing the amount of contingent liabilities at any time, such liabilities shall be computed at the amount which, in light of the facts and circumstances existing at such time, represents the amount that can reasonably be expected to become an actual or matured liability.

Specified Counterparty” means (a) prior to the Project Completion Date, each of the Construction Contractors and each guarantor party to a Parent Guarantee, (b) any counterparty to a Required LNG SPA and (c) any guarantor party to an Initial LNG SPA Guarantee or any other guarantee delivered in respect of a Required LNG SPA.

Sponsor” means Venture Global LNG, Inc., a corporation organized under the laws of the State of Delaware.

Sponsor Loan” means the loans outstanding under that certain Credit Agreement, dated as of December 6, 2018, among the Sponsor, as borrower, the lenders party thereto and Morgan Stanley Senior Funding, Inc., as administrative agent, as may be amended, amended and restated, modified or supplemented from time to time.

 

-225-

Calcasieu Pass - Common Terms Agreement


State of New York,” “New York” or “NY” means the State of New York in the United States.

Storage Tanks EPC Contract” means that certain Amended and Restated LNG Storage Tanks Engineering, Procurement and Construction Agreement, dated as of December 22, 2017, by and between the Borrower and CB&I, as amended by Amendment No. 1 to Amended and Restated LNG Storage Tanks Engineering, Procurement and Construction Agreement, dated as of April 1, 2019, and Amendment No. 2 to Amended and Restated LNG Storage Tanks Engineering, Procurement and Construction Agreement, dated as of June 30, 2019, and supplemented by Anticipated LNTP, dated as of October 1, 2018, Limited Notice to Proceed No. 2, dated as of April 1, 2019, and Limited Notice to Proceed No. 3, dated as of June 30, 2019, in each case, by and between the Borrower and CB&I.

Storm Surge Wall Construction Agreement” means that certain Construction Agreement relating to a Storm Surge Wall, dated as of February 15, 2017, by and between the Borrower and Weeks Marine, as amended by Amendment No. 1 to Construction Agreement (Storm Surge Wall), dated as of December 13, 2017, Amendment No. 2 to Construction Agreement (Storm Surge Wall), dated as of October 5, 2018, Amendment No. 3 to Construction Agreement (Storm Surge Wall), dated as of March 5, 2019, and Amendment No. 4 to Construction Agreement (Storm Surge Wall), dated as of June 28, 2019, and supplemented by Anticipated LNTP, dated as of October 5, 2018, Limited Notice to Proceed No. 2, dated as of February 22, 2019, Notice to Proceed, dated as of June 28, 2019, and that certain letter agreement re: insurance requirements prior to financial closing date, dated June 28, 2019, in each case, by and between the Borrower and Weeks Marine.

Subordinated Debt” means any unsecured debt or obligation that ranks subordinate in right of payment to the Senior Debt Obligations, on the basis set forth in a subordination agreement in the form set forth in Schedule S – 1 (Form of General Subordination Agreement) or Schedule S – 2 (Form of Obligor Subordination Agreement) to the Common Terms Agreement, as the case may be.

Subsequent Material Project Agreements” means any contract, agreement, letter agreement or other instrument (other than a Real Property Document) to which a Obligor becomes a party after the Closing Date that:

 

  (a)

replaces or substitutes for an existing Material Project Agreement (including a Replacement Material Contract);

 

  (b)

with respect to any Gas supply contract between any Obligor and any Gas supplier or any Gas transportation contract between any Obligor and any Qualified Transporter, (i) contains obligations and liabilities that are in excess of $20 million per year and (ii) is for a term that is greater than three (3) years;

 

-226-

Calcasieu Pass - Common Terms Agreement


  (c)

with respect to any contract for the delivery and sale of LNG between any Obligor and any LNG Buyer, (i) contains obligations and liabilities that are in excess of $50 million per year and (ii) is for a term that is greater than three (3) years;

 

  (d)

except as provided in clauses (b) and (c) above, contains obligations and liabilities equal to or in excess of $50 million per year and a committed term of at least two (2) years, with respect to any other contract; provided that no LNG SPA that is not a Qualifying LNG SPA (or any guarantee thereof) shall constitute a Subsequent Material Project Agreement; or

 

  (e)

is a guarantee provided in favor of any Obligor by a guarantor or a counterparty under a Subsequent Material Project Agreement.

For the purposes of this definition, any series of related transactions shall be considered as one transaction, and all contracts, agreements, letter agreements or other instruments in respect of such transactions shall be considered as one contract, agreement, letter agreement or other instrument, as applicable. Subsequent Material Project Agreements that are executed in a form previously attached to a Material Project Agreement (or Subsequent Material Project Agreement approved by the Intercreditor Agent (acting at the direction of the Requisite Intercreditor Parties)) will not be subject to the prior Intercreditor Agent approval requirements set forth in Section 12.5 (Material Project Agreements) of the Common Terms Agreement; provided that, the notice requirements in Section 10.3(o) and 10.3(p) (Notices) shall apply to such Subsequent Material Project

Agreements.

Subsidiary” means, for any Person, any corporation, partnership, joint venture, limited liability company or other entity of which at least a majority of the securities or other ownership interests having by their terms ordinary voting power to elect a majority of the board of directors or other Persons performing similar functions of such corporation, partnership or other entity (irrespective of whether or not at the time securities or other ownership interests of any other class or classes of such corporation, partnership or other entity shall have or might have voting power by reason of the happening of any contingency) is at the time directly or indirectly owned or Controlled by such Person or one or more Subsidiaries of such Person or by such Person and one or more Subsidiaries of such Person and “Subsidiaries” shall have a corresponding meaning.

Supplemental Quantity” means the positive difference between (i) 10 MTPA and (ii) the Base Committed Quantity.

 

-227-

Calcasieu Pass - Common Terms Agreement


Survey” means an American Land Title Association (“ALTA”) survey of the LNG Facility Site, dated not more than thirty (30) days prior to the Closing Date and certified to Borrower, the Intercreditor Agent and the Title Company, showing a state of facts reasonably acceptable to the Intercreditor Agent (including, without limitation, (i) the location of the LNG Facility Site, (ii) all easements benefiting the LNG Facility Site (or constituting a portion of the LNG Facility Site), all easements affecting the LNG Facility Site and all rights of way and existing utility lines referred to in the Title Policy or disclosed by a physical inspection of the LNG Facility Site, (iii) any established building lines, whether by zoning or agreement, and areas affected by restrictive covenants affecting the LNG Facility Site, (iv) adequate access to the portion of the LNG Facility Site comprising the Project Facilities, (v) encroachments, if any, and the extent thereof in feet and inches upon the LNG Facility Site and onto property adjacent to the LNG Facility Site, and (vi) any improvements, whether existing or to the extent constructed, and the relationship of such improvements by distances to the perimeter of the LNG Facility Site, established building lines and street lines), prepared by an independent surveyor licensed in the State of Louisiana in compliance with the 2016 ALTA/NSPS Minimum Standard Detail Requirements for ALTA/NSPS Surveys, satisfying those “Table A” standards reasonably required by the Collateral Agent, and otherwise sufficient for the Title Company to eliminate the standard survey exception from the Title Policy and to issue the endorsements set forth on Schedule Z (Survey Endorsements).

Swap Obligation” means any obligation to pay or perform under any agreement, contract or transaction that constitutes a “swap” within the meaning of Section 1a(47) of the Commodity Exchange Act or the regulations thereunder.

Swing Swap” means an contract which entitles the buyer of the contract to pay a fixed price for natural gas and the seller to pay the gas daily average at a defined location for a defined period of time. The Swing Swap is settled financially, via exchange of cash payment each day as the gas daily average is settled, rather than physically.

Taxes” means all present or future taxes, levies, imposts, duties, deductions, withholdings, assessments, fees or other charges, including any interest, additions to tax or penalties applicable thereto, imposed by any Governmental Authority or the government of any foreign jurisdiction, or of any political subdivision thereof, including any and all agencies, branches, departments and administrative and other subdivisions thereof, and any payments in lieu of the foregoing.

TBtu” means one trillion Btus.

Term Loan Availability Period” has the meaning given to it in the Credit Facility Agreement.

Term Loan Commitment” has the meaning given in Exhibit A (Definitions) to the Credit Facility Agreement.

Term Loans” has the meaning given in the Credit Facility Agreement.

 

-228-

Calcasieu Pass - Common Terms Agreement


Third Party Account Bank” has the meaning given in Section 4.11(a) (Third Party Investment Account) of the Common Security and Account Agreement.

Third Party Investment Account” has the meaning given in Section 4.11(a) (Third Party Investment Account) of the Common Security and Account Agreement.

Title Company” means Chicago Title Insurance Company and First American Title Insurance Company.

Title Policy” means one or more fully paid ALTA Loan Policies of Title Insurance (Form 2016) of title insurance as adopted for use in the State of Louisiana, or a pro forma policy prepared prior to payment for, issuance and delivery of the policy, with completed Schedules A and B, showing the proposed insured, the amount of insurance, the exceptions that are proposed to be placed in the final policies to be issued, and the name of the title insurance company and title insurance agent, including all amendments and endorsements thereto, issued by the Title Company in favor of the Collateral Agent, with such coinsurers or reinsurers as may be reasonably required by the Collateral Agent, with such policies:

 

  (a)

in the case of the Title Policy delivered in connection with the Closing Date, in an amount equal to $3,832,500,000.00;

 

  (b)

in the case of a Title Policy obtained in connection with an acquisition of Real Estate after the Closing Date, to the extent that the Obligors are required to obtain such policy in respect of such Real Estate acquisition pursuant to the Common Terms Agreement or Common Security and Account Agreement, then:

(x) in the case such acquisition of Real Estate is for purposes of an Expansion or Development Expenditure to be funded by Loans incurred by the Obligors, the Obligors shall either amend the then-existing Title Policy, replace the then-existing Title Policy with a new Title Policy or, to the extent a tie-in endorsement to the then existing Title Policy obtained in connection with incurrence of Loans is available and obtained, obtain a separate incremental Title Policy covering the acquired Real Estate; and

(y) in the case of an acquisition of any Real Estate by the Obligors other than in the circumstances described in clause (x) above, the Obligors may (but shall not be required to) amend the then-existing Title Policy or replace the then-existing Title Policy with a new Title Policy in an amount consistent with the terms in clause (x) above or shall obtain a Title Policy covering only such acquired Real Estate in an amount not less than the market value, as reasonably determined by the Borrower, of such acquired Real Estate;

 

-229-

Calcasieu Pass - Common Terms Agreement


in each case with respect to such acquired Real Estate, and in form or forms satisfactory to the Collateral Agent in all respects, with such policies when taken together insuring as of the date of the recording of the applicable mortgage required under Section 3.2(f) (Security Interests to be Granted by the Obligors – Real Property) of the Common Security and Account Agreement creating a Lien on the estates and interests in the Real Estate comprising the LNG Facility, that such mortgage is a first and prior Lien on the estates and interests in the real property comprising the LNG Facility (to the extent the mortgage property consists of interests insurable under the terms of such form of title policy) free and clear of all Liens on and defects of title other than Permitted Liens, and containing or providing for, among other items:

 

  (a)

no survey exceptions other than those approved by the Collateral Agent; and

 

  (b)

such other endorsements and affirmative assurances (including, to the extent available on commercially reasonable terms, materialmen’s and mechanic’s lien coverage) as the Collateral Agent shall reasonably require and which the title insurers are permitted and willing to issue pursuant to applicable Louisiana Government Rules.

Trade Secret Licenses” means any and all agreements providing for the granting of any right in or to Trade Secrets (whether a Obligor is licensee or licensor thereunder) or otherwise providing for a covenant not to sue for misappropriation or other violation of a Trade Secret.

Trade Secrets” means all trade secrets and all other confidential or proprietary information and know-how, manufacturing and production processes and techniques, inventions, research and development information, technical data, financial, marketing and business data, pricing and cost information, business and marketing plans, and customer and supplier lists and information whether or not the foregoing has been reduced to a writing or other tangible form, including all documents and things embodying, incorporating, or referring in any way to the foregoing, and with respect to any and all of the foregoing:

 

  (a)

all rights to sue or otherwise recover for any past, present and future misappropriation or other violation thereof;

 

  (b)

all proceeds of the foregoing, including license fees, royalties, income, payments, claims, damages, and proceeds of suit now or hereafter due and/or payable with respect thereto; and

 

  (c)

all other rights of any kind accruing thereunder or pertaining thereto throughout the world.

 

-230-

Calcasieu Pass - Common Terms Agreement


Trademark Licenses” means any and all agreements, licenses and covenants providing for the granting of any right in or to any Trademark or otherwise providing for a covenant not to sue for infringement, dilution or other violation of any Trademark or permitting coexistence with respect to a Trademark (whether a Obligor is licensee or licensor thereunder).

Trademarks” means all United States, foreign and multinational trademarks, trade names, trade styles, trade dress, corporate names, company names, business names, fictitious business names, Internet domain names, service marks, certification marks, collective marks, logos, other source or business identifiers, designs and general intangibles of a like nature, whether or not registered, and with respect to any and all of the foregoing:

 

  (a)

all registrations and applications therefor including the registrations and applications required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Trademarks” (as such schedule may be amended from time to time);

 

  (b)

all extensions and renewals of any of the foregoing and amendments thereto;

 

  (c)

all of the goodwill of the business connected with the use of and symbolized by any of the foregoing;

 

  (d)

all rights to sue or otherwise recover for any past, present and future infringement, dilution or other violation of any of the foregoing or for any injury to the related goodwill;

 

  (e)

all proceeds of the foregoing, including license fees, royalties, income, payments, claims, damages, and proceeds of suit now or hereafter due and/or payable with respect thereto; and

 

  (f)

all other rights of any kind accruing thereunder or pertaining thereto throughout the world.

Transaction Documents” means, collectively, the Finance Documents and the Material Project Agreements.

TransCameron Pipeline” means the development, design, financing, engineering, procurement, construction, installation, tying-in, testing, commissioning, completion, ownership, insurance, operation and maintenance of a 42-inch diameter, approximately 24-mile long natural gas pipeline and related facilities that will extend to the LNG Facility from interconnection points within the vicinity of Grand Chenier Station in Cameron Parish, Louisiana.

Transfers” has the meaning given in the relevant Facility Agreement.

UCC” means the Uniform Commercial Code (or any similar or equivalent legislation) as in effect from time to time in any applicable jurisdiction.

 

-231-

Calcasieu Pass - Common Terms Agreement


United States” or “US” means the United States of America.

Unmatured Event of Default” means an Unmatured Loan Facility Event of Default, Unmatured Indenture Event of Default or a comparable unmatured event of default under any other Senior Debt Instrument entered into after the date of the Common Security and Account Agreement.

Unmatured Indenture Event of Default” means an event that, with the giving of notice, lapse of time or making of a determination, would constitute an Indenture Event of Default.

Unmatured LNG SPA Prepayment Event” means an event that, with the giving of notice or lapse of a cure period, would become an LNG SPA Prepayment Event.

Unmatured Loan Facility Event of Default” means a misrepresentation, breach of undertaking or other event or condition that has occurred and that, with the giving of notice or lapse of time or making of a determination, would constitute a Loan Facility Event of Default.

UOP” means UOP LLC.

US Dollars” and “$” means the currency of the United States.

US Tax Compliance Certificate” has the meaning given in Section 21.5(b)(ii)(C) (Status of Facility Lenders and Facility Agents) of the Common Terms Agreement.

USA Patriot Act” means the Uniting and Strengthening America by Providing Appropriate Tools Required to Intercept and Obstruct Terrorism Act of 2001, as amended from time to time.

USPTO” means the United States Patent and Trademark Office.

Weeks Marine” means Weeks Marine, Inc.

Withdrawal and Transfer Certificate” means a certificate, in the form attached as Schedule K (Form of Withdrawal and Transfer Certificate) to the Common Security and Account Agreement.

Withdrawal Liability” means any liability to a Multiemployer Plan as a result of a complete or partial withdrawal from such Multiemployer Plan, as such terms are defined in Sections 4203 and 4205 of ERISA.

Working Capital Availability Period” has the meaning given in the Credit Facility Agreement.

 

-232-

Calcasieu Pass - Common Terms Agreement


Working Capital Debt” has the meaning given in Section 6.2 (Working Capital Debt) of the Common Terms Agreement.

Working Capital Facility” has the meaning given in the Credit Facility Agreement.

Working Capital Lenders” has the meaning given in the Credit Facility Agreement.

Working Capital Loan Availability Period” has the meaning given in the Credit Facility Agreement.

Working Capital Loans” has the meaning given in the Credit Facility Agreement.

Write-Down and Conversion Powers” means, with respect to any EEA Resolution Authority, the write-down and conversion powers of such EEA Resolution Authority from time to time under the Bail-In Legislation for the applicable EEA Member Country, which write-down and conversion powers are described in the EU Bail-In Legislation Schedule.

Louisiana Defined Terms. As used in the Common Terms Agreement, the Common Security Account Agreement or another Finance Document, but without intending to alter or derogate from the choice of applicable law set forth in Section 23.12 of the Common Terms Agreement or in another provision of a Finance Document, the following terms have the following meanings: “real property” and “real estate” shall include immovable property; “fee simple” shall include full ownership; “personal property” shall include movable property; “tangible property” shall include corporeal property; “intangible property” shall include incorporeal property; “easements” shall include servitudes; “buildings” shall be deemed to include other constructions; “county” shall include a parish; the term “joint and several liability” and words of similar import shall be deemed to include in solido liability; and references to the UCC or the Uniform Commercial Code shall include the Louisiana Commercial Laws, La. R.S. §§ 10:1-101 et seq.

 

-233-

Calcasieu Pass - Common Terms Agreement


Final

SCHEDULE B-1

DISBURSEMENT REQUEST FORM (TERM LOANS)

[Omitted]


SCHEDULE B-2

DISBURSEMENT REQUEST FORM (WORKING CAPITAL LOANS)

[Omitted]


SCHEDULE B-3

ISSUANCE REQUEST FORM (LETTERS OF CREDIT)

[Omitted]


SCHEDULE C

TABLE OF REQUIREMENTS FOR LEGAL OPINIONS – CONDITIONS TO CLOSING

[Omitted]


SCHEDULE D-1

FORM OF CONSTRUCTION BUDGET

[Omitted]


SCHEDULE D-2

FORM OF CONSTRUCTION SCHEDULE

[Omitted]


SCHEDULE E

KNOW YOUR CUSTOMER DOCUMENTATION

[Omitted]


SCHEDULE F

MATERIAL PERMITS

[Omitted]


SCHEDULE G

DISCLOSURE SCHEDULE

[Omitted]


SCHEDULE H

MATERIAL PROJECT AGREEMENT AND CERTAIN OTHER CONTRACTS

[Omitted]


SCHEDULE I

CHANGE ORDERS

[Omitted]


SCHEDULE J

TRANSACTIONS WITH AFFILIATES

[Omitted]


SCHEDULE K

GAS SOURCING PLAN

[Omitted]


SCHEDULE L

SCHEDULE OF MINIMUM INSURANCE

[Omitted]


SCHEDULE M

INDEPENDENT INSURANCE EXPERTS

[Omitted]


SCHEDULE N

SENIOR CREDITORS’ ADVISORS AND CONSULTANTS

[Omitted]


SCHEDULE O

LENDERS’ RELIABILITY TEST CRITERIA

[Omitted]


SCHEDULE P-1

REPLACEMENT FACILITY AGENT ACCESSION AGREEMENT

[Omitted]


SCHEDULE P-2

NEW FACILITY AGENT ACCESSION AGREEMENT (ADDITIONAL SENIOR DEBT)

[Omitted]


SCHEDULE Q-1

ADDRESSES FOR NOTICES TO OBLIGORS

[Omitted]


SCHEDULE Q-2

ADDRESSES FOR NOTICES TO FACILITY AGENTS AND FACILITY LENDERS

[Omitted]


SCHEDULE R

BASE CASE FORECAST

[Omitted]


SCHEDULE S-1

FORM OF GENERAL SUBORDINATION AGREEMENT

[Omitted]


SCHEDULE S-2

FORM OF OBLIGOR SUBORDINATION AGREEMENT

[Omitted]


SCHEDULE T

KNOWLEDGE PARTIES

(Definition of “Knowledge” – Schedule A to the Common Terms Agreement)

 

Name

  

Title

Robert Pender    Co-Chief Executive Officer
Michael Sabel    Co-Chief Executive Officer
D. Michael Eberhart    Chief Financial Officer
Keith Larson    General Counsel
Fory Musser    Senior Vice President, Development
Tom Newton    Senior Vice President, Engineering
Jim Strohman    Senior Vice President, Project Director for Calcasieu Pass

 

T-1

Calcasieu Pass - Common Terms Agreement Schedules


SCHEDULE U

REAL PROPERTY DOCUMENTS

(Definition of “Real Property Documents” – Schedule A to the Common Terms Agreement)

 

1.

Amended and Restated Ground Lease Agreement, dated as of June 20, 2019, by and between Venture Global Calcasieu Pass, LLC, and Henry Venture, LLC, amending and restating the Ground Lease Agreement dated as of March 11, 2019, as amended by that certain First Amendment to Ground Lease Agreement dated as of March 25, 2019.

 

2.

Amended and Restated Ground Lease Agreement, dated as of July 15, 2019, by and between Venture Global Calcasieu Pass, LLC, and JADP Venture, LLC, amending and restating the Ground Lease Agreement dated as of March 14, 2019, as amended by that certain First Amendment to Ground Lease Agreement dated as of March 25, 2019.

 

3.

Lease, dated as of June 7, 2019, by and between Mermentau Mineral & Land Co., Inc., and TransCameron Pipeline, LLC (Tracts East 1.00, 2.00, 4.00, 5.00)

 

U-1

Calcasieu Pass - Common Terms Agreement Schedules


SCHEDULE V

SCHEDULE OF CERTAIN REAL PROPERTY RIGHTS

[Omitted]


SCHEDULE W

FORM OF DISBURSEMENT ENDORSEMENT

[Omitted]


SCHEDULE X

PHASE I ENVIRONMENTAL ASSESSMENTS

[Omitted]


SCHEDULE Y

DISQUALIFIED INSTITUTIONS

(Definition of “Disqualified Institution” – Schedule A to the Common Terms Agreement)

[Omitted]

 

Y-1

Calcasieu Pass - Common Terms Agreement Schedules


SCHEDULE Z

SURVEY ENDORSEMENTS

(Definitions “Survey Endorsements”)

 

1. ALTA 9.7-06    Restrictions, Encroachments, Minerals – Land Under Development
2. ALTA 17-06    Access and Entry
3. ALTA 17.2-06    Utility Access
4. ALTA 19-06    Contiguity-Multiple Parcels
5. ALTA 25-06    Same as Survey

 

Z-1

Calcasieu Pass - Common Terms Agreement Schedules


SCHEDULE 5.1(F)(II)

PRIOR LOCATIONS

[Omitted]


SCHEDULE 5.2(M)

REAL PROPERTY INTERESTS

[Omitted]

Exhibit 10.74

Execution Version

CONSENT AND AMENDMENT TO THE COMMON TERMS AGREEMENT AND THE

CREDIT FACILITY AGREEMENT

This CONSENT AND AMENDMENT TO THE COMMON TERMS AGREEMENT AND THE CREDIT FACILITY AGREEMENT (this “Consent and Amendment”), dated as of December 28, 2020, is in respect of (a) the Common Terms Agreement, dated as of August 19, 2019 (as amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”), by and among Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Borrower”), TransCameron Pipeline, LLC (the “Guarantor”), Natixis, New York Branch, as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties (in such capacity, the “Credit Facility Agent”), each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Mizuho Bank, Ltd., as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”) and (b) the Credit Facility Agreement, dated as of August 19, 2019 (as amended, amended and restated, modified or supplemented from time to time, the “Credit Facility Agreement”), by and among the Borrower, the Guarantor, the Lenders party thereto from time to time, the Issuing Banks party thereto from time to time, the Credit Facility Agent, and solely for purposes of Section 3.06 thereof, Mizuho Bank (USA), as Collateral Agent (in such capacity, the “Collateral Agent”). All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Common Terms Agreement, or if not defined therein, the Credit Facility Agreement. For all purposes of this Consent and Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.

WHEREAS, pursuant to Section 12.27(a) of the Common Terms Agreement, the Borrower shall comply in all material respects with Schedule K (Gas Sourcing Plan) of the Common Terms Agreement;

WHEREAS, Schedule K (Gas Sourcing Plan) of the Common Terms Agreement requires the Borrower, prior to December 31, 2020, to have entered into arrangements for at least 1,000,000 MMBtu/d of firm natural gas supply for a minimum term of three years;

WHEREAS, the Borrower does not expect to meet the foregoing requirement prior to December 31, 2020;

WHEREAS, pursuant to Section 12.27(a)(ii) of the Common Terms Agreement, Schedule K (Gas Sourcing Plan) of the Common Terms Agreement may be updated from time to time by mutual agreement of the Borrower and the Intercreditor Agent (acting on the instruction of the Requisite Intercreditor Parties, whose consent to updates of such gas sourcing plan shall not be unreasonably withheld, conditioned or delayed if determined to be reasonable by the Market Consultant and/or Independent Engineer, as appropriate);

WHEREAS, the Independent Engineer has determined it to be reasonable to update Schedule K (Gas Sourcing Plan) to the Common Terms Agreement to extend the deadline of December 31, 2020 to have entered into arrangements for at least 1,000,000 MMBtu/d of firm natural gas supply for a minimum term of three years to September 30, 2021 (such extension, the “Gas Sourcing Plan Extension”); and


WHEREAS, in connection with the foregoing, the Borrower has requested that the Credit Facility Agent, the Intercreditor Agent and the Credit Facility Lenders constituting the Required Lenders under the Credit Facility Agreement (collectively, the “ Lenders” and each individually, a “Lender”) consent and agree, and the Credit Facility Agent, the Intercreditor Agent and the Lenders are willing to consent and agree, to amend Schedule K (Gas Sourcing Plan) to the Commons Terms Agreement to reflect the Gas Sourcing Plan Extension on the terms and conditions set forth herein.

NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1. Consent and Amendment. Upon the effectiveness of this Consent and Amendment in accordance with Section 2 below, (i) each of the Lenders party hereto, the Credit Facility Agent (at the direction of Required Lenders) and the Intercreditor Agent hereby consent and agree to amend Schedule K (Gas Sourcing Plan) of the Common Terms Agreement to reflect the Gas Sourcing Plan Extension and (ii) Schedule K (Gas Sourcing Plan) of the Common Terms Agreement shall be deemed amended by replacing the reference to “December 31, 2020” therein with “September 30, 2021”.

Section 2. Effectiveness. This Consent and Amendment shall become effective as of the date hereof only upon delivery of executed counterparts of this Consent and Amendment by each of (a) the Borrower, (b) the Guarantor, (c) the Intercreditor Agent, (d) the Credit Facility Agent (who constitutes the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement)), and (e) Lenders constituting the Required Lenders under the Credit Facility Agreement.

Section 3. Representations and Warranties. Each of the Obligors hereby represents and warrants to the Lenders, Credit Facility Agent and Intercreditor Agent that:

3.1 upon the effectiveness of the consent and amendment set forth in Section 1, no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing or will result from the consummation of the transactions contemplated by this Consent and Amendment; and

3.2 upon the effectiveness of the consent and amendment set forth in Section 1, each of the representations and warranties of the Obligors in the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents is true and correct in all material respects except (A) for those representations and warranties that are qualified by materiality, which shall be true and correct in all respects, on and as of the date hereof (or, if stated to have been made solely as of an earlier date, as of such earlier date) and (B) for the representations and warranties set forth in Section 5.1 (Initial Representations and Warranties of the Obligors) of the Common Terms Agreement, which are made only on the Closing Date.


Section 4. Financing Document. This Consent and Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement.

Section 5. Governing Law. THIS CONSENT AND AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA.

Section 6. Headings. All headings in this Consent and Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.

Section 7. Binding Nature and Benefit; Amendment. This Consent and Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Consent and Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 8. Counterparts. This Consent and Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Consent and Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Consent and Amendment.

Section 9. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Consent and Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Consent and Amendment apply to any other matters.

Section 10. Direction to Credit Facility Agent and Intercreditor Agent.

10.1 by their signature below, each of the undersigned Credit Facility Lenders instructs the Credit Facility Agent to (i) execute this Consent and Amendment and (ii) direct the Intercreditor Agent to execute this Consent and Amendment; and

10.2 based on the instructions above, the Credit Facility Agent, constituting the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement), hereby directs the Intercreditor Agent to execute this Consent and Amendment.

[Remainder of the page left intentionally blank.]


IN WITNESS WHEREOF, the Parties have caused this Consent and Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as the Borrower

By:   /s/ Keith Larson
Name: Keith Larson
Title: General Counsel

TRANSCAMERON PIPELINE, LLC,

as the Guarantor

By:   /s/ Keith Larson
Name: Keith Larson
Title: General Counsel
Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

By:   /s/ Lisa Wong     /s/ Valerie Du Mars
Name: Lisa Wong    Name: Valerie Du Mars
Title: Director     Title: Executive Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Intercreditor Agent

By:   /s/ Brian Caldwell
Name: Brian Caldwell
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.

as Lender

By:   /s/ Brian Caldwell
Name: Brian Caldwell
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

GOLDMAN SACHS BANK USA,

as Lender

By:   /s/ Mahesh Mohan
Name: Mahesh Mohan
Title: Authorized Signatory

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

WOORI GLOBAL INFRASTRUCTURE SYNERGY-UP FUND,

as Lender

By:   /s/ Seung Won Kwak
Name: Seung Won Kwak
Title: Manager

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Aozora Bank, Ltd.

as Lender

By:   /s/ Takashi Kometani
Name:Takashi Kometani
Title: Senior Vice President and Group Head, Project Finance Group

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Bank Gospodarstwa Krajowego,

as Lender

By:   /s/ Sylwia Sieminska
Name: Sylwia Sieminska
By:   /s/ Maryla Posyniak
Name: Maryla Posyniak

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Bank of America, N.A.,

as Lender

By:   /s/ Ronald E. McKaig
Name: Ronald E. McKaig
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

CIT Bank, N.A.,

as Lender

By:   /s/ Joseph Gyurindak
Name: Joseph Gyurindak
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

FirstBank Puerto Rico d/b/a FirstBank Florida,

as Lender

By:   /s/ Jose M. Lacasa
Name: Jose M. Lacasa
Title: SVP, Corporate Banking

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

ING Capital LLC,

as Lender

By:   /s/ Tanja van der Woude
Name: Tanja van der Woude
Title: Director
By:   /s/ Anthony Rivera
Name: Anthony Rivera
Title: Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

JPMORGAN CHASE BANK N.A.,

as Lender

By:   /s/ Arina Mavilian
Name: Arina Mavilian
Title: Executive Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Landesbank Baden-Württemberg New York Branch,

as Lender

By:   /s/ Adam Rahal
Name: Adam Rahal
Title: Legal Counsel
By:   /s/ Michael Thier
Name: Michael Thier
Title: Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Morgan Stanley Senior Funding, Inc.,

as Lender

By:   /s/ Rikin Pandya
Name: Rikin Pandya
Title: Vice President

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

NOMURA CORPORATE FUNDING AMERICAS, LLC,

as Lender

By:   /s/ Vinod Mukani
Name: Vinod Mukani
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Royal Bank of Canada,

as Lender

By:   /s/ Jason S. York
Name: Jason S. York
Title: Authorized Signatory

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

BANCO DE SABADELL, S.A., MIAMI BRANCH,

as Lender

By:   /s/ Ignacio Alcaraz
Name: Ignacio Alcaraz
Title: Head of Structured Finance Americas

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Banco Santander, S.A., New York Branch,

as Lender

By:   /s/ Nuno Andrade
Name: Nuno Andrade
Title: Managing Director
By:   /s/ Pablo Urgoiti
Name: Pablo Urgoiti
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

LANDESBANK HESSEN-THUERINGEN GIROZENTRALE, NEW YORK BRANCH,

as Lender

By:   /s/ David A Leech
Name: David A Leech
Title: Senior Vice President Credit Risk Management Corporate Finance New York
By:   /s/ Raf Goebel
Name: Raf Goebel
Title: Vice President

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

CaixaBank,

as Lender

By:   /s/ Antoni Jofre
Name: Antoni Jofre
Title: Director/PoA
By:   /s/ Helena Torres
Name: Helena Torres
Title: Director /PoA

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR NATWEST GROUP PENSION FUND (AA SECTION),

as Lender

By:   /s/ Lisa Shaw
Name: Lisa Show
Title: Attorney
By:   /s/ Jinny Hwang
Name: Jinny Hwang
Title: Attorney

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR NATWEST GROUP PENSION FUND (MAIN FUND SECTION),

as Lender

By:   /s/ Lisa Shaw
Name: Lisa Shaw
Title: Attorney
By:   /s/ Jinny Hwang
Name: Jinny Hwang
Title: Attorney

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

KFW IPEX-BANK GMBH,

as Lender

By:   /s/ Simone Thrun
Name: Simone Thrun
Title: Director
By:   /s/ Dorothee Schwenk
Name: Dorothee Schwenk
Title: Assistant Vice President

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Sumitomo Mitsui Banking Corporation,

as Lender

By:   /s/ Takahiro Date
Name: Takahiro Date
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

SPT Infrastructure Finance Sub-4, LLC,

as Lender

By:   /s/ Haig Najarian
Name: Haig Najarian
Title: Authorized Signatory

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Industrial and Commercial Bank of China Limited,

New York Branch,

as Lender

By:   /s/ Michael Merrow
Name: Michael Merrow
Title: Vice President
By:   /s/ Michael Fabisiak
Name: Michael Fabisiak
Title: Head of Project Finance

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT

Exhibit 10.75

Execution Version

SECOND AMENDMENT TO THE COMMON TERMS AGREEMENT AND CONSENT

TO THE CREDIT FACILITY AGREEMENT

This SECOND AMENDMENT TO THE COMMON TERMS AGREEMENT AND CONSENT TO THE CREDIT FACILITY AGREEMENT (this “Second Amendment”), dated as of January 26, 2021, is in respect of (a) the Common Terms Agreement, dated as of August 19, 2019, by and among Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Borrower”), TransCameron Pipeline, LLC (the “Guarantor”), Natixis, New York Branch, as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties (in such capacity, the “Credit Facility Agent”), each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Mizuho Bank, Ltd., as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”), as amended by that certain Consent and Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement (the “First Amendment”), dated as of December 28, 2020, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”) and (b) the Credit Facility Agreement, dated as of August 19, 2019 (as amended, amended and restated, modified or supplemented from time to time, the “Credit Facility Agreement”), by and among the Borrower, the Guarantor, the Lenders party thereto from time to time, the Issuing Banks party thereto from time to time, the Credit Facility Agent, and solely for purposes of Section 3.06 thereof, Mizuho Bank (USA), as Collateral Agent (in such capacity, the “Collateral Agent”). All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Common Terms Agreement, or if not defined therein, the Credit Facility Agreement. For all purposes of this Second Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.

WHEREAS, the Borrower has requested that the Credit Facility Lenders under the Credit Facility Agreement (collectively, the “Lenders” and each individually, a “Lender”), the Credit Facility Agent and the Intercreditor Agent consent and agree, and the Lenders constituting the Required Lenders, the Credit Facility Agent and the Intercreditor Agent are willing to consent and agree, to amend the Commons Terms Agreement on the terms and conditions set forth herein and in accordance with Section 23.15 of the Commons Terms Agreement, Section 4 of the Intercreditor Agreement and Section 11.01 of the Credit Facility Agreement.

NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1. Consent and Amendment. Upon the effectiveness of this Second Amendment in accordance with Section 2 below, each of the Lenders party hereto, the Credit Facility Agent (at the direction of Required Lenders) and the Intercreditor Agent hereby consent and agree to amend the Common Terms Agreement as follows:

1.1 Section 12.5(h) (Material Project Agreements) of the Common Terms Agreement shall be amended by replacing the references to “such Subsequent Material Project Agreement” in clauses (i), (ii), (iii) and (v) thereof with “such new Material Project Agreement or such Subsequent Material Project Agreement”.


1.2 Clause (l) of the definition of “Material Project Agreements” set forth on Section 1.3 of Schedule A of the Common Terms Agreement shall be amended by replacing the reference to “three (3) years” in clause (A) thereof with “five (5) years”.

1.3 Clause (m) of the definition of “Material Project Agreements” set forth on Section 1.3 of Schedule A of the Common Terms Agreement shall be amended by replacing the reference to “(k)” with “(l)”.

1.4 Clause (n) of the definition of “Material Project Agreements” set forth on Section 1.3 of Schedule A of the Common Terms Agreement shall be amended by replacing the reference to “(l)” with “(m)”.

1.5 The definition of “Material Project Counterparties” set forth on Section 1.3 of Schedule A of the Common Terms Agreement shall be amended by deleting such definition in its entirety and replacing it with the following:

Material Project Counterparties” means each of the Construction Contractors, the Initial LNG Buyers, Shell Oil Company, Galp Energia, SGPS, S.A., BP International Limited, Repsol Exploracion, S.A., Texas Eastern Transmission, LP, ANR Pipeline Company, Bridgeline Holdings, L.P., EnLink Midstream Operating, LP, Sabine Pipe Line LLC, Indigo Minerals LLC, Calcasieu Pass Operations, LLC, Venture Global Services, LLC, TransCameron Operations, LLC, Henry Venture, LLC, JADP Venture, LLC, General Electric Company, McDermott International, Inc., Honeywell International Inc., CP Marine Offloading, LLC and each other party (other than an Obligor) to a Material Project Agreement.

1.6 The definition of “Permitted Payments” set forth on Section 1.3 of Schedule A of the Common Terms Agreement shall be amended by replacing the reference to “Material Project Documents” in clause (a) thereof with “Material Project Agreements”.

1.7 The definition of “Subsequent Material Project Agreement” set forth on Section 1.3 of Schedule A of the Common Terms Agreement shall be amended by replacing the reference to “three (3) years” in clause (b) thereof with “five (5) years”.

Section 2. Effectiveness. This Second Amendment shall become effective as of the date hereof only upon delivery of executed counterparts of this Second Amendment by each of (a) the Borrower, (b) the Guarantor, (c) the Intercreditor Agent, (d) the Credit Facility Agent (who constitutes the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement)) and (e) Lenders constituting the Required Lenders under the Credit Facility Agreement.

 

2


Section 3. Representations and Warranties. Each of the Obligors hereby represents and warrants to the Lenders, Credit Facility Agent and Intercreditor Agent that:

3.1 upon the effectiveness of the consent and amendments set forth in Section 1, no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing or will result from the consummation of the transactions contemplated by this Second Amendment; and

3.2 upon the effectiveness of the consent and amendments set forth in Section 1, each of the representations and warranties of the Obligors in the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents is true and correct in all material respects except (A) for those representations and warranties that are qualified by materiality, which shall be true and correct in all respects, on and as of the date hereof (or, if stated to have been made solely as of an earlier date, as of such earlier date) and (B) for the representations and warranties set forth in Section 5.1 (Initial Representations and Warranties of the Obligors) of the Common Terms Agreement, which are made only on the Closing Date.

Section 4. Finance Document. This Second Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement. Each of the parties hereto agree that each reference to “Common Terms Agreement” in each Finance Document, including the Intercreditor Agreement and Credit Facility Agreement, shall refer to the Common Terms Agreement as amended by the First Amendment and as amended hereby.

Section 5. Governing Law. THIS SECOND AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA.

Section 6. Headings. All headings in this Second Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.

Section 7. Binding Nature and Benefit; Amendment. This Second Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Second Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 8. Counterparts. This Second Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Second Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Second Amendment.

Section 9. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Second Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Second Amendment apply to any other matters.

 

3


Section 10. E-Signature. The words “execution,” “signed,” “signature,” and words of like import in this Second Amendment shall be deemed to include electronic signatures or electronic records, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any legal requirements, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

Section 11. Direction to Credit Facility Agent and Intercreditor Agent.

11.1 By their signature below, each of the undersigned Credit Facility Lenders instructs the Credit Facility Agent to (i) execute this Second Amendment and (ii) direct the Intercreditor Agent to execute this Second Amendment; and

11.2 Based on the instructions above, the Credit Facility Agent, constituting the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement), hereby directs the Intercreditor Agent to execute this Second Amendment.

[Remainder of the page left intentionally blank.]

 

4


IN WITNESS WHEREOF, the Parties have caused this Second Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as the Borrower

By:   /s/ Keith Larson
  Name: Keith Larson
  Title: Secretary

TRANSCAMERON PIPELINE, LLC,

as the Guarantor

By:   /s/ Keith Larson
  Name: Keith Larson
  Title: Secretary

 

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

By:   /s/ Lisa Wong
Name:   Lisa Wong
Title:   Director
By:   /s/ Frederic Bouley
Name:   Frederic Bouley
Title:   Vice President

 

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Intercreditor Agent

By:   /s/ Brian Caldwell
Name:   Brian Caldwell
Title:   Managing Director

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

BASISGV/PX (Investments) Ltd.,

as Lender

By:   /s/ Laurie Harding
Name:   Laurie Harding
Title:   Director

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Bank Gospodarstwa Krajowego,

as Lender

By:   /s/ Maryla Posyniak
Name:   Maryla Posyniak
By:   /s/ Sylwia Sieminska
Name:   Sylwia Sieminska

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

BANK OF AMERICA, N.A.,

as Lender

By:   /s/ Ronald E. McKaig
Name: Ronald E. McKaig
Title: Managing Director

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

CaixaBank,

as Lender

By:   /s/ Antoni Jofre
Name: Antoni Jofre
Title: Director/PoA
By:   /s/ Helena Torres
Name: Helena Torres
Title: Director/PoA

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

CIT Bank, N.A.,

as Lender

By:   /s/ Joseph Gyurindak
Name: Joseph Gyurindak
Title: Managing Director

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

LANDESBANK HESSEN-THÜRINGE GIROZENTRALE, NEW YORK BRANCH,

as Lender

By:   /s/ David A. Leech
Name: David A. Leech
Title: Senior Vice President
Credit Risk Management Corporate Finance New York
By:   /s/ Raf Goebel
Name: Raf Goebel
Title: Vice President

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

FirstBank Puerto Rico d/b/a FirstBank Florida,

as Lender

By:   /s/ Jose M. Lacasa
Name: Jose M. Lacasa
Title: SVP, Corporate Banking

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Goldman Sachs Bank USA,

as Lender

By:   /s/ Mahesh Mohan
Name: Mahesh Mohan
Title: Authorized Signatory

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

ING Capital LLC,

as Lender

By:   /s/ Subha Pasumarti
Name: Subha Pasumarti
Title: Managing Director
By:   /s/ Gabriel D’Huart
Name: Gabriel D’Huart
Title: Vice President

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

JPMORGAN CHASE BANK N.A.,

as Lender

By:   /s/ Arina Mavilian
Name: Arina Mavilian
Title: Executive Director

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

LANDESBANK BADEN-WÜRTTEMBERG, NEW YORK BRANCH,

as Lender

By:   /s/ Leonard Crann
Name: Leonard Crann
Title: Head of Americas Region
By:   /s/ Adam Rahal
Name: Adam Rahal
Title: Legal Counsel

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

BANCO DE SABADELL, S.A., MIAMI BRANCH,

as Lender

By:   /s/ Ignacio Alcaraz
Name: Ignacio Alcaraz
Title: Head of Structured Finance Americas

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Banco Santander, S.A., New York Branch,

as Lender

By:   /s/ Pablo Urgoiti
Name: Pablo Urgoiti
Title: Managing Director
By:   /s/ Nuno Andrade
Name: Nuno Andrade
Title: Managing Director

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Sumitomo Mitsui Banking Corporation,

as Lender

By:   /s/ Juan Kreutz
Name: Juan Kreutz
Title: Managing Director

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Wori America Bank,

as Lender

By:   /s/ Young Suk Song
Name: Young Suk Song
Title: SVP

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Lender

By:   /s/ Brian Caldwell
Name: Brian Caldwell
Title: Managing Director

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Lender

By:   /s/ Amit Roy
Name: Amit Roy
Title: Executive Director
By:   /s/ Nasir Khan
Name: Nasir Khan
Title: Managing Director

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

NOMURA CORPORATE FUNDING

AMERICAS, LLC,

as Lender

By:   /s/ Vinod Mukani
Name: Vinod Mukani
Title: Managing Director

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

ROYAL BANK OF CANADA,

as Lender

By:   /s/ Jason S. York
Name: Jason S. York
Title: Authorized Signatory

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR NATWEST GROUP PENSION FUND (AA SECTION),

as Lender

By:   /s/ Lisa Shaw
Name: Lisa Shaw
Title: Attorney
By:   /s/ Jinny Hwang
Name: Jinny Hwang
Title: Attorney

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR NATWEST GROUP PENSION FUND (MAIN FUND SECTION),

as Lender

By:   /s/ Lisa Shaw
Name: Lisa Shaw
Title: Attorney
By:   /s/ Jinny Hwang
Name: Jinny Hwang
Title: Attorney

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

WOORI GLOBAL INFRASTRUCTURE

SYNERGY-UP FUND,

as Lender

By:   /s/ Seung Won Kwak
Name: Seung Won Kwak
Title: Manager

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Morgan Stanley Senior Funding, Inc.,

as Lender

By:   /s/ Rikin Pandya
Name: Rikin Pandya
Title: Vice President

 

SIGNATURE PAGE TO SECOND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

KFW IPEX-BANK GMBH,

as Lender

By:   /s/ Thrun
Name: Thrun
Title: Director
By:   /s/ Anton
Name: Anton
Title: Assistant Vice President

 

SIGNATURE PAGE TO SECOND AMENDMENT

Exhibit 10.76

Execution Version

CONSENT AND AMENDMENT TO CREDIT FACILITY AGREEMENT

This CONSENT AND AMENDMENT TO CREDIT FACILITY AGREEMENT (this “Consent and Amendment”), dated as of September 30, 2021, is in respect of the Credit Facility Agreement, dated as of August 19, 2019 (as amended, amended and restated, modified or supplemented from time to time, the “Credit Facility Agreement”), by and among Venture Global Calcasieu Pass, LLC (the “Borrower”), TransCameron Pipeline, LLC (the “Guarantor”, and together with the Borrower, the “Obligors”), the Lenders party thereto from time to time, the Issuing Banks party thereto from time to time, Natixis, New York Branch, as the Credit Facility Agent (in such capacity, the “Credit Facility Agent”), and solely for purposes of Section 3.06 thereof, Mizuho Bank (USA), as Collateral Agent (in such capacity, the “Collateral Agent”). All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Credit Facility Agreement, or if not defined therein, the Common Terms Agreement, dated as of August 19, 2019 (as amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”), by and among the Borrower, the Guarantor, the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties, each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Mizuho Bank, Ltd., as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”); provided, that capitalized terms used herein in Section 4 and not otherwise defined shall have the meanings ascribed to such terms in the Common Security and Account Agreement. For all purposes of this Consent and Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 (Interpretation) of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.

WHEREAS, pursuant to Section 2.09 of the Credit Facility Agreement, the Borrower may by written notice to the Credit Facility Agent request increases in the Working Capital Commitments (together with any applicable corresponding increases in the Issuing Bank Limits and Fronting Limits) up to an aggregate principal amount not to exceed the maximum amount of Working Capital Debt permitted pursuant to Section 6.2(a) (Working Capital Debt) of the Common Terms Agreement;

WHEREAS, pursuant Section 6.2(a) (Working Capital Debt) of the Common Terms Agreement, the Borrower may incur Working Capital Debt not exceeding an amount outstanding at any one time equal to the sum of (i) an aggregate principal amount not to exceed the amount of the Working Capital Facility as of the Closing Date and (ii) $255,000,000 on the terms and conditions thereof;

WHEREAS, in accordance with Section 2.09(a) of the Credit Facility Agreement and Section 6.2(a) of the Common Terms Agreement, the Borrower delivered to the Credit Facility Agent the Working Capital Commitment Increase Notice on September 10, 2021 requesting an increase in the Working Capital Commitment of each Working Capital Lender party hereto in the aggregate principal amount of $255,000,000 and corresponding increases in the Issuing Bank Limit and the Fronting Limit of each Issuing Bank party hereto, in each case, as set forth on Exhibit A hereto;


WHEREAS, each Working Capital Lender and each Issuing Bank party hereto (each, an “Incremental Lender/Issuing Bank”, and in the individual roles of Working Capital Lender and Issuing Bank, an “Incremental Lender” and an “Incremental Issuing Bank”, respectively) is willing to increase its Working Capital Commitment, Issuing Bank Limit and/or Fronting Limit, as applicable (such increases in commitments or limits, the “Upsized Commitments/Limits”), as set forth opposite its name on Exhibit A hereto;

WHEREAS, the Borrower requests that each Incremental Lender/Issuing Bank waive the requirement pursuant to Section 2.09(b) of the Credit Facility Agreement that the effective date of the Upsized Commitments/Limits be a date not less than thirty (30) days after the date on which the Working Capital Commitment Increase Notice was delivered to the Credit Facility Agent; and

WHEREAS, in connection with the foregoing and pursuant to Section 2.09(c) of the Credit Facility Agreement and Section 6.2(a) of the Common Terms Agreement, the Borrower has requested that the Credit Facility Agent and each Incremental Lender/Issuing Bank consent and agree, and the Credit Facility Agent and each Incremental Lender/Issuing Bank are willing to consent and agree, to amend the Credit Facility Agreement to reflect the increased Working Capital Commitments, Issuing Bank Limits and Fronting Limits on the terms and conditions set forth herein.

NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1. Consent and Amendment; Waiver. Upon the effectiveness of this Consent and Amendment in accordance with Section 3 below, each Incremental Lender/Issuing Bank party hereto hereby (a) consents and agrees (i) to increase its Working Capital Commitment, Issuing Bank Limit and/or Fronting Limit, as applicable, as set forth opposite its name on Exhibit A hereto and (ii) that the section titled “Working Capital Commitments” on Schedule I (Lenders, Commitments) to the Credit Facility Agreement and Schedule II (Issuing Bank Limits) to the Credit Facility Agreement are hereby amended and restated in their entirety and replaced by Schedule A and Schedule B hereto, respectively. The parties hereto acknowledge and agree that this Consent and Amendment shall constitute an Incremental Amendment pursuant to the Credit Facility Agreement; and (b) notwithstanding anything to the contrary in Section 2.09(b) of the Credit Facility Agreement or any other Finance Documents, consents and agrees to waive the requirement that the date on which the Upsized Commitments/Limits become effective shall be a date not less than thirty (30) days after the date on which the Working Capital Commitment Increase Notice was delivered to the Credit Facility Agent.

Section 2. Terms of Upsized Commitments/Limits; Addition of Issuing Bank.

2.1 Terms of Upsized Commitments/Limits. The Applicable Margin, covenants, payment terms, voluntary and mandatory prepayments and other provisions applicable to (a) the Upsized Commitments/Limits consisting of increases to the Working Capital Commitments shall be the same as such provisions applicable to the existing Working Capital Commitments, (b) the Upsized Commitments/Limits consisting of increases to the Issuing Bank Limits shall be the same as such provisions applicable to the existing Issuing Bank Limits and (c)


the Upsized Commitments/Limits consisting of increases to the Fronting Limits shall be the same as such provisions applicable to the existing Fronting Limits. Each of the Lenders increasing their Working Capital Commitments shall be paid a one-time underwriting fee equal to 1.5% of the amount by which such Lender’s Working Capital Commitment has increased, which fee shall be fully earned as of the Effective Date and non-refundable under any circumstances and payable to the Credit Facility Agent for the account of each such Lender within ten (10) Business Days after the date hereof.

2.2 Addition of Issuing Bank. Borrower hereby identifies and designates The Bank of Nova Scotia, Houston Branch as an “Issuing Bank” under the Credit Facility Agreement pursuant to the definition of “Issuing Bank” in the Credit Facility Agreement with the Fronting Limit and Issuing Bank Limit as set forth on Exhibit A, and, by its signature herein, The Bank of Nova Scotia, Houston Branch hereby agrees to accept such designation as an Issuing Bank and to be bound by all of the terms contained in the Credit Facility Agreement and the other Finance Documents binding on an Issuing Bank in such capacity, in each case, subject to the terms and conditions of the Credit Facility Agreement.

Section 3. Effectiveness; Representations and Warranties.

3.1 Effectiveness. This Consent and Amendment shall become effective as of the date on which each of the following conditions precedent has been satisfied (the “Effective Date”):

(a) delivery of executed counterparts of this Consent and Amendment by each of (i) the Borrower, (ii) the Credit Facility Agent and (ii) each Incremental Lender/Issuing Bank party hereto;

(b) satisfaction of the each of the other conditions set forth in Section 2.09(c) of the Credit Facility Agreement; and

(c) the Intercreditor Agent has received, at least three (3) Business Days prior to the Effective Date, a certificate from the Borrower that (1) identifies each holder of Working Capital Commitments (after giving effect to the Upsized Commitments/Limits contemplated herein) and (2) attaches a copy of the proposed form of this Consent and Amendment.

3.2 Representations and Warranties. The Borrower hereby represents and warrants to each Incremental Lender/Issuing Bank and the Credit Facility Agent that, as of the Effective Date:

(a) no Loan Facility Event of Default or Unmatured Loan Facility Event of Default exists before or after giving effect to the Upsized Commitments/Limits;

(b) since the time of the financial statements most recently provided pursuant to Section 10.1(a) (Accounting, Financial and Other Information) of the Common Terms Agreement, no developments have occurred which, individually or in the aggregate, have resulted in or could reasonably be expected to result in a Material Adverse Effect; and


(c) each of the Repeated Representations made by each Obligor is true and correct in all material respects, except for those representations and warranties that are qualified by materiality, which are true and correct in all respects, as to such Obligor on and as of the Effective Date (or, if stated to have been made solely as of an earlier date, as of such earlier date) (it being understood and agreed that, for purposes of the representations and warranties contemplated by this clause (c), the Credit Facility Agreement shall be as amended by this Consent and Amendment, and this Consent and Amendment shall be a Transaction Document).

Section 4. Security.

4.1 Common Security and Account Agreement. As security for the payment in full in US Dollars or the performance in full, as the case may be, of the Senior Debt Obligations (which include Senior Debt Obligations arising under the Credit Facility Agreement, as amended by this Consent and Amendment), each Obligor confirms and agrees that, pursuant to the Common Security and Account Agreement, it has collaterally assigned, pledged and granted, and as of the date hereof it continues to collaterally assign, pledge and grant, to the Collateral Agent, for the ratable benefit of the Secured Parties, a continuing Lien on all of such Obligor’s right, title and interest whether now owned or hereafter existing or acquired in, to and under the Collateral described in the Common Security and Account Agreement, including Section 3.2 thereof.

4.2 Pledge Agreement. As security for the payment in full in US Dollars or the performance in full, as the case may be, of the Senior Debt Obligations (which include Senior Debt Obligations arising under the Credit Facility Agreement, as amended by this Consent and Amendment), the Pledgor confirms and agrees that, pursuant to the Pledge Agreement, it has collaterally assigned, pledged and granted, and as of the date hereof it continues to collaterally assign, pledge and grant, to the Collateral Agent, for the ratable benefit of the Secured Parties, a continuing Lien on all of the Pledgor’s right, title and interest whether now owned or hereafter existing or acquired in, to and under the Collateral described in the Pledge Agreement, including Section 2.1 thereof.

Section 5. Financing Document. This Consent and Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement.

Section 6. Governing Law; Jurisdiction; Etc..

6.1 Governing Law. THIS CONSENT AND AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK.

6.2 Jurisdiction; Etc. The provisions of Sections 11.03(b), 11.03(c), 11.03(d) and 11.03(e) of the Credit Facility Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.

Section 7. Headings. All headings in this Consent and Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.


Section 8. Binding Nature and Benefit; Amendment. This Consent and Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Consent and Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 9. Severability. The provisions of Section 11.14 of the Credit Facility Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.

Section 10. Counterparts. This Consent and Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Consent and Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Consent and Amendment.

Section 11. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Credit Facility Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Consent and Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Consent and Amendment apply to any other matters.

Section 12. Effect of Amendment. From and after the Effective Date, any reference in the Credit Facility Agreement or any Finance Document or other documents, certificates or instruments related thereto or annexes, schedules or exhibits referring to the Credit Facility Agreement or any component thereof shall be deemed to refer to the Credit Facility Agreement or component thereof as amended by this Consent and Amendment and references in the Credit Facility Agreement to “this Agreement” (including indirect references such as “hereunder”, “hereby”, “herein” and “hereof”) shall be deemed to be references to the Credit Facility Agreement as amended hereby.

Section 13. Electronic Execution. The words “execution,” “execute”, “signed,” “signature,” and words of like import in or related to any document to be signed in connection with this Consent and Amendment and the transactions contemplated hereby shall be deemed to include electronic signatures, the electronic matching of assignment terms and contract formations on electronic platforms, or the keeping of records in electronic form, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any applicable law, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state, provincial or territorial laws based on the Uniform Electronic Transactions Act.

[Remainder of the page left intentionally blank.]


IN WITNESS WHEREOF, the Parties have caused this Consent and Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as the Borrower

By:   /s/ Keith Larson
Name: Keith Larson
Title: General Counsel and Secretary

TRANSCAMERON PIPELINE, LLC,

as the Guarantor

By:   /s/ Keith Larson
Name: Keith Larson
Title: General Counsel and Secretary

CALCASIEU PASS PLEDGOR, LLC,

as the Pledgor

By:   /s/ Keith Larson
Name: Keith Larson
Title: General Counsel and Secretary

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

By:   /s/ Frederic Bouley
Name: Frederic Bouley
Title: Director
By:   /s/ Urs Fischer
Name: Urs Fischer
Title: Executive Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

CAIXABANK, S.A.,

as Incremental Lender/Issuing Bank

By:   /s/ Antoni Jofre & Helena Torres

Name: Antoni Jofre & Helena Torres

Title: Director & Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

SUMITOMO MITSUI BANKING CORPORATION,

as Incremental Lender/Issuing Bank

By:   /s/ Juan Kreutz
Name: Juan Kreutz
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.
PROJECT AND TRADE FINANCE CORE FUND
AND

FEDERATED HERMES PROJECT AND TRADE FINANCE TENDER FUND,

as Incremental Lenders/Issuing Banks

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.
GOLDMAN SACHS BANK USA,
as Incremental Lender/Issuing Bank
By:   /s/ Jacob Elder
Name: Jacob Elder
Title: Authorized Signatory

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

ING CAPITAL LLC,

as Incremental Lender/Issuing Bank

By:   /s/ Subha Pasumarti
Name: Subha Pasumarti
Title: Managing Director
By:   /s/ Gabriel D’Huart
Name: Gabriel D’Huart
Title: Vice President

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

ROYAL BANK OF CANADA,

as Incremental Lender/Issuing Bank

By:   /s/ Jason S. York
Name: Jason S. York
Title: Authorized Signatory

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Incremental Lender/Issuing Bank

By:   /s/ Junji Hasegawa
Name: Junji Hasegawa
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

Banco Santander, S.A., New York Branch,

as Incremental Lender/Issuing Bank

By:   /s/ Nuno Andrade
Name: Nuno Andrade
Title: Managing Director
By:   /s/ Daniel Kostman
Name: Daniel Kostman
Title: Executive Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

THE BANK OF NOVA SCOTIA, HOUSTON BRANCH,

as Incremental Lender/Issuing Bank

By:   /s/ Joe Lattanzi
Name: Joe Lattanzi
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

JPMORGAN CHASE BANK N.A.,

as Incremental Lender/Issuing Bank

By:   /s/ Sofia Barrera Jaime
Name: Sofia Barrera Jaime
Title: Vice President

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

BANK OF AMERICA, N.A.,

as Incremental Lender/Issuing Bank

By:   /s/ Ronald E. McKaig
Name: Ronald E. McKaig
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Incremental Lender/Issuing Bank

By:   /s/ Amit Roy
Name: Amit Roy
Title: Executive Director
By:   /s/ Nasir Khan
Name: Nasir Khan
Title: Managing Director

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

INDUSTRIAL AND COMMERCIAL BANK OF CHINA LIMITED, NEW YORK BRANCH,

as Incremental Lender/Issuing Bank

By:   /s/ Alexandra Grossman
Name: Alexandra Grossman
By:   /s/ Michael Fabisiak
Name: Michael Fabisiak

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Acknowledged and agreed as of the first date set forth above.

NOMURA CORPORATE FUNDING AMERICAS, LLC,

as Incremental Lender/Issuing Bank

By:   /s/ Vinod Mukani
Name: Vinod Mukani
Title: Managing Director


Acknowledged and agreed as of the first date set forth above.

MORGAN STANLEY SENIOR FUNDING, INC.,

as Incremental Lender/Issuing Bank

By:   /s/ Michael Pasquarello
Name: Michael Pasquarello
Title: Vice President

 

SIGNATURE PAGE TO CONSENT AND AMENDMENT


Exhibit A

Working Capital Commitment Increase, Issuing Bank Limit Increase, and Fronting Limit

Increase

[Omitted]

Exhibit 10.77

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

THIRD AMENDMENT TO THE COMMON TERMS AGREEMENT, FIRST

AMENDMENT TO THE COMMON SECURITY AND ACCOUNT AGREEMENT AND

CONSENT TO THE CREDIT FACILITY AGREEMENT

This THIRD AMENDMENT TO THE COMMON TERMS AGREEMENT, FIRST AMENDMENT TO THE COMMON SECURITY AND ACCOUNT AGREEMENT AND CONSENT TO THE CREDIT FACILITY AGREEMENT (this “Amendment”), dated as of May 25, 2022 (the “Effective Date”), is in respect of (a) the Common Terms Agreement, dated as of August 19, 2019, by and among Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Borrower”), TransCameron Pipeline, LLC (the “Guarantor”), Natixis, New York Branch, as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties (in such capacity, the “Credit Facility Agent”), each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Mizuho Bank, Ltd., as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”), as amended by that certain Consent and Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of December 28, 2020, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent and that certain Second Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of January 26, 2021, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”), (b) the Common Security and Account Agreement, dated as of August 19, 2019, by and among the Borrower, the Guarantor, the Senior Creditor Group Representatives from time to time party thereto, the Intercreditor Agent, Mizuho Bank (USA), as Collateral Agent (in such capacity, the “Collateral Agent”) and Mizuho Bank, Ltd., as the account bank (as amended, amended and restated, modified or supplemented from time to time, the “Common Security and Account Agreement”) and (c) the Credit Facility Agreement, dated as of August 19, 2019, by and among the Borrower, the Guarantor, the Lenders party thereto from time to time, the Issuing Banks party thereto from time to time, the Credit Facility Agent, and solely for purposes of Section 3.06 thereof, the Collateral Agent, as amended by that certain Consent and Amendment to Credit Facility Agreement, dated as of September 30, 2021, by and among the Borrower, the Guarantor, Calcasieu Pass Pledgor, LLC, as pledgor, the Credit Facility Agent and the Incremental Lender/Issuing Banks party thereto (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Credit Facility Agreement”). All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Common Terms Agreement, or if not defined therein, the Credit Facility Agreement. For all purposes of this Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.


WHEREAS, the Borrower has requested that the Credit Facility Lenders under the Credit Facility Agreement (collectively, the “Lenders” and each individually, a “Lender”), the Credit Facility Agent, the Collateral Agent and the Intercreditor Agent consent and agree, and the Lenders constituting the Required Lenders, the Credit Facility Agent, the Collateral Agent and the Intercreditor Agent are willing to consent and agree, to amend the Commons Terms Agreement and the Common Security and Account Agreement, as applicable, on the terms and conditions set forth herein and in accordance with Section 23.15 of the Commons Terms Agreement, Section 4 of the Intercreditor Agreement, Section 12.14 of the Common Security and Account Agreement and Section 11.01 of the Credit Facility Agreement.

NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1. Consent and Amendments.

1.1 Consent and Amendments to Common Terns Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, each of the Lenders party hereto, the Credit Facility Agent (at the direction of Required Lenders) and the Intercreditor Agent hereby consent and agree to amend the Common Terms Agreement as follows:

(a) Section 8.3(a) (Amendment of LNG SPAs) of the Common Terms Agreement shall be amended by replacing the words “any amendment or modification of the price or quantity provisions of any Qualifying LNG SPA” with the words “any amendment or modification of the price or quantity provisions of any Qualifying LNG SPA (other than any increase thereof)”.

(b) Section 8.4(a) (Sale of Supplemental Quantity) of the Common Terms Agreement shall be amended by replacing the words “The Borrower shall be permitted to enter into LNG SPAs in respect of all or any portion of the Supplemental Quantity, which LNG SPAs may be of any duration, on any terms and to buyers of any credit quality;” with the words “The Borrower shall be permitted to (x) enter into LNG SPAs, which LNG SPAs may be of any duration, on any terms and to buyers of any credit quality or (y) increase the quantity provisions under existing LNG SPAs, in respect of all or any portion of the Supplemental Quantity;”.

(c) Article 11 (Restricted Payments) of the Common Terms Agreement shall be amended by adding the following as a new Section 11.3 (Pre-Completion Restricted Payments):

11.3 Pre-Completion Restricted Payments

Notwithstanding anything to the contrary in the Finance Documents (including, for the avoidance of doubt, Section 11.1 (Conditions to Restricted Payments)), Restricted Payments may be made prior to the Project Completion Date no more than once per calendar month, if each of the following conditions has been satisfied:

(a) no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing or could reasonably be expected to occur as a result of such Restricted Payment;

 

2


(b) no outstanding LC Loans or LC Reimbursement Payments are outstanding as of the date of such Restricted Payment;

(c) the then-Required LNG SPAs are in full force and effect and no actual LNG SPA Prepayment Event or Unmatured LNG SPA Prepayment Event has occurred and is continuing in respect of which the prepayment and cancellation required by the occurrence of such event in accordance with Section 8.2 (LNG SPA Mandatory Prepayment) has not been made in full;

(d) after giving effect to such Restricted Payment, the Senior Debt/Equity Ratio shall be no greater than 75:25;

(e) LNG Production System Substantial Completion (as defined in the EPC Contract) in respect of LPS1 has occurred;

(f) the Borrower has delivered to the Intercreditor Agent a certification from the Independent Engineer confirming (i) that it reasonably expects the Project Completion Date to be achieved by the Date Certain and (ii) that after giving effect to such Restricted Payment, the Obligors will have funds (excluding any funds required pursuant to Section 11.3(g)(ii)(y)) equal to or in excess of the Required Completion Amount (as defined below);

(g)

(i) the sum of, after giving effect to such Restricted Payment, (A) amounts on deposit in the Contingency Reserve Account, (B) amounts on deposit in the Construction Account, (C) amounts on deposit in the Pre-Completion Revenues Account and (D) the amounts of any committed, but undrawn, Senior Debt Commitment available to the Borrower

equals or exceeds

(ii) the sum of:

(x) the amount of funds that are, as of the date of such Restricted Payment, reasonably required to achieve the Project Completion Date (excluding any amounts required to be funded in the Senior Facilities Debt Service Reserve Account and each other Additional Debt Service Reserve Account (if any) (or, if the Senior Facilities Debt Service Reserve Account or any such Additional Debt Service Reserve Account is not yet required to be funded, the amount that will be required to be funded therein on the first date on which such account is required to be funded)) by the Date Certain (such amount, the “Required Completion Amount”); and

 

3


(y) (I) prior to LNG Production System Substantial Completion (as defined in the EPC Contract) in respect of LPS3, $[***], (II) on or after LNG Production System Substantial Completion (as defined in the EPC Contract) in respect of LPS3, $[***], and (III) on or after Facility Substantial Completion (as such term is defined in the EPC Contract), the greater of (1) $[***] and (2) the amount required to be funded in the Senior Facilities Debt Service Reserve Account and each other Additional Debt Service Reserve Account (if any) (or, if the Senior Facilities Debt Service Reserve Account or any such Additional Debt Service Reserve Account is not yet required to be funded, the amount that will be required to be funded therein on the first date on which such account is required to be funded);

(h) the Fixed Projected DSCR for the 12-month period beginning on the then projected first Quarterly Payment Date in respect of the Term Loans to occur after the Project Completion Date is at least 1.25:1.00;

(i) since the last delivery by the Independent Engineer of the monthly construction report as provided by Section 10.4 (Construction Reports), the Borrower has not become aware of any event or circumstance the occurrence of which could reasonably be expected to (i) increase the total Project Costs materially above those set forth in the Construction Budget and Schedule (except to the extent the funds specified in clause (g)(i) above are reasonably anticipated to be sufficient to cover such costs), or (ii) have a Material Adverse Effect; and

(j) at least two Business Days prior to the proposed date of such Restricted Payment, the Intercreditor Agent has received a certificate from the Borrower confirming that each of the conditions set forth in this Section 11.3 ( Pre-Completion Restricted Payments) has been satisfied and setting forth the calculation of the Fixed Projected DSCR in clause (i) above.

1.2 Consent and Amendment to Common Security and Account Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, the Collateral Agent (at the direction of the Intercreditor Agent) hereby consents and agrees to amend the Common Security and Account Agreement as follows:

(a) Clause (D) of Section 4.5(b)(ii) (Pre-Completion Revenues Account) of the Common Security and Account Agreement shall be amended and restated as follows:

“(D) fourth, no more frequently than once per calendar month, for Restricted Payments, so long as the conditions for Restricted Payments under each Senior Debt Instrument (including Section 11.3 (Pre-Completion Restricted Payments) of the Common Terms Agreement and any comparable provision in any Senior Debt Instrument then in effect) are satisfied; and

(E) fifth, at the option of the Company, to the Contingency Reserve Account.”

 

4


Section 2. Effectiveness. This Amendment shall become effective as of the date hereof subject to satisfaction of the following conditions precedent (a) delivery of executed counterparts of this Amendment by each of (i) the Borrower, (ii) the Guarantor, (iii) the Intercreditor Agent, (iv) the Collateral Agent, (v) the Credit Facility Agent (who constitutes the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement)) and (vi) Lenders constituting the Required Lenders under the Credit Facility Agreement; (b) the Intercreditor Agent and Credit Facility Agent shall have received certified copies of the then current forecasts of LNG to be produced and loaded at the LNG Facility prior to the Project Completion Date (including then current forecasts of contracted and uncontracted revenues in respect thereof); and (c) a legal opinion in substance and form reasonably acceptable to the Intercreditor Agent as to the enforceability of this Amendment and covering such other matters relating to this Amendment as the Intercreditor Agent shall reasonably request.

Section 3. Representations and Warranties. Each of the Obligors hereby represents and warrants to the Lenders, Credit Facility Agent, Collateral Agent and Intercreditor Agent that:

3.1 upon the effectiveness of the consent and amendments set forth in Section 1, no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing or will result from the consummation of the transactions contemplated by this Amendment; and

3.2 upon the effectiveness of the consent and amendments set forth in Section 1, each of the representations and warranties of the Obligors in the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents is true and correct in all material respects except (A) for those representations and warranties that are qualified by materiality, which are true and correct in all respects on and as of the date hereof (or, if stated to have been made solely as of an earlier date, as of such earlier date) and (B) for the representations and warranties set forth in Section 5.1 (Initial Representations and Warranties of the Obligors) of the Common Terms Agreement, which were made only on the Closing Date.

Section 4. Finance Document. This Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement. Each of the parties hereto agree that (i) each reference to “Common Terms Agreement” in each Finance Document, including the Intercreditor Agreement and the Credit Facility Agreement, shall refer to the Common Terms Agreement as amended hereby and (ii) each reference to “Common Security and Account Agreement” in each Finance Document, including the Intercreditor Agreement and the Credit Facility Agreement, shall refer to the Common Security and Account Agreement as amended hereby.

Section 5. Governing Law. THIS AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA.

Section 6. Headings. All headings in this Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.

 

5


Section 7. Binding Nature and Benefit; Amendment. This Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 8. Counterparts. This Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Amendment.

Section 9. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Common Terms Agreement, the Common Security and Account Agreement, the Credit Facility Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Amendment apply to any other matters.

Section 10. E-Signature. The words “execution,” “signed,” “signature,” and words of like import in this Amendment shall be deemed to include electronic signatures or electronic records, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any legal requirements, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

Section 11. Direction to Credit Facility Agent, Intercreditor Agent and Collateral Agent.

11.1 By their signature below, each of the undersigned Credit Facility Lenders (collectively constituting the Required Lenders) instructs the Credit Facility Agent to (i) execute this Amendment and (ii) direct the Intercreditor Agent to execute this Amendment.

11.2 Based on the instructions above, the Credit Facility Agent, constituting the

Requisite Intercreditor Parties (as defined in the Intercreditor Agreement), hereby directs the Intercreditor Agent to (i) execute this Amendment and (ii) direct the Collateral Agent to execute this Amendment.

11.3 Based on the instruction above, the Intercreditor Agent hereby directs the Collateral Agent to execute this Amendment.

[Remainder of the page left intentionally blank.]

 

6


IN WITNESS WHEREOF, the Parties have caused this Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as the Borrower

By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title: Chief Financial Officer

TRANSCAMERON PIPELINE, LLC,

as the Guarantor

By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title: Chief Financial Officer

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

By:   /s/ Lisa Wong
Name: Lisa Wong
Title: Director
By:   /s/ Urs Fischer
Name: Urs Fischer
Title: Executive Director

 

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Intercreditor Agent

By:   /s/ Brian Caldwell
Name: Brian Caldwell
Title: Managing Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK (USA),

as Collateral Agent

By:   /s/ Brian Caldwell
Name: Brian Caldwell
Title: Managing Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NATIONAL BANK OF CANADA,

as Lender

By:   /s/ John Hunt
Name: John Hunt
Title: Authorized Signatory
By:   /s/ Mark Williamson
Name: Mark Williamson
Title: Authorized Signatory

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

WOORI GLOBAL INFRASTRUCTURE SYNERGY-UP FUND,

as Lender

By:   /s/ Seung Won Kwak
Name: Seung Won Kwak
Title: Manager

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

JPMORGAN CHASE BANK N.A.,

as Lender

By:   /s/ Arina Mavilian
Name: Arina Mavilian
Title: Executive Director

 

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

THE BANK OF NOVA SCOTIA, HOUSTON BRANCH,

as Lender

By:   /s/ Joe Lattanzi
Name: Joe Lattanzi
Title: Managing Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

Goldman Sachs Bank USA,

as Lender

By:   /s/ Dan Martis
Name: Dan Martis
Title: Authorized Signatory

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

FIRSTBANK PUERTO RICO d/n/a FIRSTBANK FLORIDA,

as Lender

By:   /s/ Kevin P. Flynn
Name: Kevin P. Flynn
Title: SVP, Corporate Banking Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

SPT INFRASTRUCTURE FINANCE SUB-4 LLC,

as Lender

By:   /s/ Haig Najarian
Name: Haig Najarian
Title: Authorized Signatory

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

BANCO DE SABADELL, S.A., MIAMI BRANCH,

as Lender

By:   /s/ Ignacio Alcaraz
Name: Ignacio Alcaraz
Title: Head of Structured Finance Americas

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

KFW IPEX-BANK GMBH,

as Lender

By:   /s/ Michael Noil
Name: Michael Noil
Title: Vice President
By:   /s/ Alica Greeb
Name: Alica Greeb
Title: Associate

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

ING CAPITAL LLC,

as Lender

By:   /s/ Subha Pasumarti
Name: Subha Pasumarti
Title: Managing Director
By:   /s/ Tanja van der Woude
Name: Tanja van der Woude
Title: Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

CAIXABANK, S.A.,

as Lender

By:   /s/ Helena Torres
Name: Helena Torres
Title: Director
By:   /s/ Moises Rodriguez
Name: Moises Rodriguez
Title: Assistant Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

MORGAN STANLEY SENIOR FUNDING, INC.,

as Lender

By:   /s/ Michael Pasquarello
Name: Michael Pasquarello
Title: Vice President

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

BASISGV/PX (INVESTMENTS) LTD.,

as Lender

By:   /s/ Laurie Harding
Name: Laurie Harding
Title: Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

AOZORA BANK, LTD.,

as Lender

By:   /s/ Hirokazu Aoyama
Name: Hirokazu Aoyama
Title: Senior Vice President & Group Head

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

BAYERISCHE LANDESBANK, NEW YORK BRANCH,

as Lender

By:   /s/ Andrew Kjoller
Name: Andrew Kjoller
By:   /s/ Rolf Siebert
Name: Rolf Siebert

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

LANDESBANK HESSEN-THÜRINGE GIROZENTRALE, NEW YORK BRANCH,

as Lender

By:   /s/ Eric A. Muth
Name: Eric A. Muth
Title: Senior Vice President
Credit Risk Management
Corporate Finance New York
By:   /s/ Raf Goebel
Name: Raf Goebel
Title: Vice President

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

INDUSTRIAL AND COMMERICAL BANK OF CHINA LIMITED, NEW YOK BRANCH,

as Lender

By:   Guoshen Sun
Name: Guoshen Sun

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR NATWEST GROUP PENSION FUND (AA SECTION),

as Lender

By:   /s/ Tim Cable
Name: Tim Cable
Title: Attorney
By:   /s/ Adebanke Adeyemo
Name: Adebanke Adeyemo
Title: Attorney

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR NATWEST GROUP PENSION FUND (MAIN FUND SECTION),

as Lender

By:   /s/ Tim Cable
Name: Tim Cable
Title: Attorney
By:   /s/ Adebanke Adeyemo
Name: Adebanke Adeyemo
Title: Attorney

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

ROYAL BANK OF CANADA,

as Lender

By:   /s/ Jason S. York
Name: Jason S. York
Title: Authorized Signatory

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

Federated Hermes Project and Trade Finance Master Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

Federated Hermes Project and Trade Finance Tender Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

Project and Trade Finance Core Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NOMURA CORPORATE FUNDING AMERICAS, LLC,

as Lender

By:   /s/ Vinod Mukani
Name: Vinod Mukani
Title: Managing Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Lender

By:   /s/ David B Martens
Name: David B Martens
Title: Managing Director
By:   /s/ John Sickler III
Name: John Sickler III
Title: Vice President

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

BANCO SANTANDER, S.A., NEW YORK BRANCH,

as Lender

By:   /s/ Nuno Andrade
Name: Nuno Andrade
Title: Managing Director
By:   /s/ Daniel S. Kostman
Name: Daniel S. Kostman
Title: Executive Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

DZ BANK AG DEUTSCHE ZENTRAL-GENOSSENSCHAFTSBANK, NEW YORK BRANCH,

as Lender

By:   /s/ Glenn R. Patterson
Name: Glenn R. Patterson
Title: Director
By:   /s/ Zhao Liang Deng
Name: Zhao Liang Deng
Title: Assistant Vice President

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

LANDESBANK BADEN-WÜRTTEMBERG, NEW YORK BRANCH,

as Lender

By:   /s/ A. Bruns
Name: A. Bruns
Title: Director
By:   M. Thier
Name: M. Thier
Title: Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

SUMITOMO MITSUI BANKING CORPORATION,

as Lender

By:   /s/ Juan Kreutz
Name: Juan Kreutz
Title: Managing Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CTA, FIRST AMENDMENT TO

THE CSAA AND CONSENT TO THE CFA

Exhibit 10.78

Execution Version

FOURTH AMENDMENT TO THE COMMON TERMS AGREEMENT AND SECOND

AMENDMENT TO THE CREDIT FACILITY AGREEMENT

This FOURTH AMENDMENT TO THE COMMON TERMS AGREEMENT AND SECOND AMENDMENT TO THE CREDIT FACILITY AGREEMENT (this “Amendment”), dated as of October 12, 2022 (the “Effective Date”), is in respect of (a) the Common Terms Agreement, dated as of August 19, 2019, by and among Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Borrower”), TransCameron Pipeline, LLC (the “Guarantor”), Natixis, New York Branch, as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties (in such capacity, the “Credit Facility Agent”), each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Mizuho Bank, Ltd., as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”), as amended by that certain Consent and Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of December 28, 2020, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, that certain Second Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of January 26, 2021, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, and that certain Third Amendment to the Common Terms Agreement, First Amendment to the Common Security and Account Agreement and Consent to the Credit Facility Agreement, dated as of May 25, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, Mizuho Bank (USA), as Collateral Agent (in such capacity, the “Collateral Agent”) and Intercreditor Agent (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”) and (b) the Credit Facility Agreement, dated as of August 19, 2019, by and among the Borrower, the Guarantor, the Lenders party thereto from time to time, the Issuing Banks party thereto from time to time, the Credit Facility Agent, and solely for purposes of Section 3.06 thereof, the Collateral Agent, as amended by that certain Consent and Amendment to Credit Facility Agreement, dated as of September 30, 2021, by and among the Borrower, the Guarantor, Calcasieu Pass Pledgor, LLC, as pledgor, the Credit Facility Agent and the Incremental Lender/Issuing Banks party thereto (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Credit Facility Agreement”). All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Common Terms Agreement, or if not defined therein, the Credit Facility Agreement. For all purposes of this Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.


WHEREAS, the Borrower has requested that the Credit Facility Lenders under the Credit Facility Agreement (collectively, the “Lenders” and each individually, a “Lender”), the Credit Facility Agent and the Intercreditor Agent consent and agree, and the Lenders constituting the Required Lenders, the Credit Facility Agent and the Intercreditor Agent are willing to consent and agree, to amend the Commons Terms Agreement and the Credit Facility Agreement, as applicable, on the terms and conditions set forth herein and in accordance with Section 23.15 of the Commons Terms Agreement, Section 4 of the Intercreditor Agreement, and Section 11.01 of the Credit Facility Agreement.

NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1. Consents and Amendments.

1.1 Consents and Amendments to Common Terms Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, each of the Lenders party hereto, the Credit Facility Agent (at the direction of Required Lenders) and the Intercreditor Agent hereby consent and agree to amend the Common Terms Agreement as follows:

(a) The definition of “Date Certain” in Section 1.3 (Definitions) of Schedule A (Common Definitions and Rules of Interpretation) to the Common Terms Agreement shall be amended and restated in its entirety as follows:

““Date Certain” means September 27, 2023 provided that if, on or prior to September 27, 2023, the Borrower certifies to the Intercreditor Agent (and the Independent Engineer reasonably concurs with such certification in writing) that (i) the only remaining condition to the Project Completion Date as of the date of delivery of such certification, other than conditions that can only be satisfied on the Project Completion Date, is the condition specified in Section 14.1(c)(iii) (Conditions to Occurrence of the Project Completion Date – Physical Completion Certificate) and (ii) the Lenders’ Reliability Test has commenced in accordance with the procedures specified in Section 12.11 (Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages) and is reasonably expected to be completed on or prior to December 27, 2023, then for all purposes under this Agreement the “Date Certain” means December 27, 2023.”

(b) Section 14.1(d) (Conditions to Occurrence of the Project Completion Date) of the Common Terms Agreement shall be amended and restated in its entirety as follows:

“(d) Commercial Operation Date

 

2


Receipt by the Intercreditor Agent of a duly executed certificate of the Borrower certifying that the Commercial Operation Date under each of the Required LNG SPAs then in effect has timely occurred.”

1.2 Consent and Amendment to Credit Facility Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, the Credit Facility Agent (at the direction of Required Lenders) hereby consents and agrees to amend the Credit Facility Agreement as follows:

(a) Section 2.02(a)(i) (Term Loan Availability) of the Credit Facility Agreement shall be amended by replacing the words “the Date Certain” with “March 31, 2023”.

(b) Section 4.01(b)(ii) (Repayment of Term Loans) of the Credit Facility Agreement shall be amended and restated in its entirety as follows:

“(ii) March 31, 2023.”

Section 2. Effectiveness. This Amendment shall become effective as of the date hereof subject to satisfaction of the following conditions precedent:

2.1 delivery of executed counterparts of this Amendment by each of (i) the Borrower, (ii) the Guarantor, (iii) the Intercreditor Agent, (iv) the Credit Facility Agent (who constitutes the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement)) and (v) Lenders constituting the Required Lenders under the Credit Facility Agreement;

2.2 the Intercreditor Agent and the Credit Facility Agent shall have received an updated Construction Budget and Schedule;

2.3 the Intercreditor Agent and the Credit Facility Agent shall have received a certificate from the Borrower certifying that:

(a) since the last delivery by the Independent Engineer of the monthly construction report as provided by Section 10.4 (Construction Reports) of the Common Terms Agreement, the Borrower has not become aware of any event or circumstance the occurrence of which could reasonably be expected to (i) increase the total Project Costs materially above those set forth in the Construction Budget and Schedule (as updated pursuant to Section 2.2), or (ii) have a Material Adverse Effect;

(b)

(i) the sum of (A) amounts on deposit in the Contingency Reserve Account, (B) amounts on deposit in the Construction Account, (C) amounts on deposit in the Pre-Completion Revenues Account, and (D) the amounts of any committed, but undrawn, Senior Debt Commitment available to the Borrower

 

3


equals or exceeds

(ii) the amount of funds that are, as of the date hereof, reasonably required to achieve the Project Completion Date (excluding any amounts required to be funded in the Senior Facilities Debt Service Reserve Account and each other Additional Debt Service Reserve Account (if any) (or, if the Senior Facilities Debt Service Reserve Account or any such Additional Debt Service Reserve Account is not yet required to be funded, the amount that will be required to be funded therein on the first date on which such account is required to be funded)) by the Date Certain (as amended by this Amendment) (such amount in this clause (ii), the “Required Completion Amount”);

(c) the Borrower reasonably believes that Project Completion Date shall occur on or prior to the Date Certain (as amended by this Amendment).

2.4 the Borrower has delivered to the Intercreditor Agent a certification from the Independent Engineer confirming (a) that it reasonably expects the Project Completion Date to be achieved by the Date Certain (as amended by this Amendment) and (b) the Obligors have funds equal to or in excess of the Required Completion Amount.

Section 3. Representations and Warranties. Each of the Obligors hereby represents and warrants to the Lenders, Credit Facility Agent and Intercreditor Agent that:

3.1 upon the effectiveness of the consents and amendments set forth in Section 1, no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing or will result from the consummation of the transactions contemplated by this Amendment; and

3.2 upon the effectiveness of the consents and amendments set forth in Section 1, each of the representations and warranties of the Obligors in the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents is true and correct in all material respects except (A) for those representations and warranties that are qualified by materiality, which are true and correct in all respects on and as of the date hereof (or, if stated to have been made solely as of an earlier date, as of such earlier date) and (B) for the representations and warranties set forth in Section 5.1 (Initial Representations and Warranties of the Obligors) of the Common Terms Agreement, which were made only on the Closing Date.

 

4


Section 4. Finance Document. This Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement. Each of the parties hereto agree that (i) each reference to “Common Terms Agreement” in each Finance Document, including the Intercreditor Agreement and the Credit Facility Agreement, shall refer to the Common Terms Agreement as amended hereby and (ii) each reference to “Credit Facility Agreement” in each Finance Document, including the Intercreditor Agreement and the Common Terms Agreement, shall refer to the Credit Facility Agreement as amended hereby.

Section 5. Governing Law. THIS AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA.

Section 6. Headings. All headings in this Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.

Section 7. Binding Nature and Benefit; Amendment. This Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 8. Counterparts. This Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Amendment.

Section 9. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Amendment apply to any other matters.

Section 10. E-Signature. The words “execution,” “signed,” “signature,” and words of like import in this Amendment shall be deemed to include electronic signatures or electronic records, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any legal requirements, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

 

5


Section 11. Direction to Credit Facility Agent and Intercreditor Agent.

11.1 By their signature below, each of the undersigned Credit Facility Lenders (collectively constituting the Required Lenders) instructs the Credit Facility Agent to (i) execute this Amendment and (ii) direct the Intercreditor Agent to execute this Amendment.

11.2 Based on the instructions above, the Credit Facility Agent, constituting the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement), hereby directs the Intercreditor Agent to execute this Amendment.

[Remainder of the page left intentionally blank.]

 

6


IN WITNESS WHEREOF, the Parties have caused this Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as the Borrower

By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title: Chief Financial Officer

TRANSCAMERON PIPELINE, LLC,

as the Guarantor

By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title: Chief Financial Officer

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Intercreditor Agent

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title: Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

By:   /s/ Lisa Wong
Name: Lisa Wong
Title: Director
By:   /s/ Frederic Bouley
Name: Frederic Bouley
Title: Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

BANCO SANTANDER, S.A., NEW YORK BRANCH,

as Lender

By:   /s/ Daniel S. Kostman
Name: Daniel S. Kostman
Title: ED
By:   /s/ Erika Wershoven
Name: Erika Wershoven
Title: Executive Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

Bank Gospodarstwa Krajowego,

as Lender

By:   /s/ Karol Cecot
Name: Karol Cecot
Title: Proxy
By:   /s/ Sylwia Sieminska
Name: Sylvia Sieminska
Title: Proxy

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

BANK OF AMERICA, N.A.,

as Lender

By:   /s/ Ronald E. McKaig
Name: Ronald E. McKaig
Title: Managing Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

BASISGV/PX (INVESTMENTS) LTD.,

as Lender

By:   /s/ Laurie Harding
Name: Laurie Harding
Title: Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

BAYERISCHE LANDESBANK, NEW YORK BRANCH,

as Lender

By:   /s/ Kareem Hartl
Name: Kareem Hartl
Title: Vice President
By:   /s/ Guss Hobbs
Name: Guss Hobbs
Title: Vice President

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

CAIXABANK, S.A.,

as Lender

By:   /s/ Maria Luisa Cobos
Name: Maria Luisa Cobos
Title: Director
By:   /s/ Berta Guadalupe Egaña
Name: Berta Guadalupe Egaña
Title: Assistant Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

DZ BANK AG DEUTSCHE ZENTRAL- GENOSSENSCHAFTSBANK, NEW YORK BRANCH,

as Lender

By:   /s/ Glenn R. Patterson
Name: Glenn R. Patterson
Title: Director
By:   /s/ Zhao Liang Deng
Name: Zhao Liang Deng
Title: Assistant Vice President

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

Federated Hermes Project and Trade Finance Master Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

Federated Hermes Project and Trade Finance

Tender Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

FIRST-CITIZENS BANK & TRUST COMPANY,

as Lender

By:   /s/ Stephen Norcross
Name: Stephen Norcross
Title: Vice President

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

FIRSTBANK PUERTO RICO d/n/a FIRSTBANK FLORIDA,

as Lender

By:   /s/ Kevin P. Flynn
Name: Kevin P. Flynn
Title: SVP, Corporate Banking Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

Goldman Sachs Bank USA,

as Lender

By:   /s/ Keshia Leday
Name: Keshia Leday
Title: Authorized Signatory

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

INDUSTRIAL AND COMMERICAL BANK OF CHINA LIMITED, NEW YOK BRANCH,

as Lender

By:   /s/ Lin (Allan) Sun
Name: Lin (Allan) Sun
Title: Head of Project and Infrastructure Finance
By:   /s/ Stefano Di Genua
Name: Stefano Di Genua
Title: VP - Project and Infrastructure Finance

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

ING CAPITAL LLC,

as Lender

By:   /s/ Subha Pasumarti
Name: Subha Pasumarti
Title: Managing Director
By:   /s/ Benjamin Velazquez
Name: Benjamin Velazquez
Title: Managing Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

JPMORGAN CHASE BANK N.A.,

as Lender

By:   /s/ Arina Mavilian
Name: Arina Mavilian
Title: Executive Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

KFW IPEX-BANK GMBH,

as Lender

By:   /s/ Michael Noil
Name: Michael Noil
Title: Vice President
By:   /s/ Dorothee Schwenk
Name: Dorothee Schwenk
Title: Ass. Vice President

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

LANDESBANK BADEN-WÜRTTEMBERG, NEW YORK BRANCH,

as Lender

By:   /s/ Oliver Langel
Name: Oliver Langel
Title: Director
By:   /s/ Michael Thier
Name: Michael Thier
Title: Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Lender

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title: Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

MORGAN STANLEY SENIOR FUNDING, INC.,

as Lender

By:   /s/ Rikin Pandya
Name: Rikin Pandya
Title: Vice President

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

MUNICH REINSURANCE AMERICA, INC.,

as Lender

By:   /s/ Oliver J. Horbelt
Name: Oliver J. Horbelt
Title: SVP and Chief Financial Officer
By:   /s/ Ganesh Narayan
Name: Ganesh Narayan
Title: Vice President & Controller

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NATIONAL BANK OF CANADA,

as Lender

By:   /s/ Andrew Nguyen
Name: Andrew Nguyen
Title: Authorized Signatory
By:   /s/ John Hunt
Name: John Hunt
Title: Authorized Signatory

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Lender

By:   /s/ David B Martens
Name: David B Martens
Title: Managing Director
By:   /s/ John Sickler III
Name: John Sickler III
Title: Vice President

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR NATWEST

GROUP PENSION FUND (AA SECTION),

as Lender

By:   /s/ Cameron Price
Name: Cameron Price
Title: Authorised Signatory
By:   /s/ Nick Cleary
Name: Nick Cleary
Title: Authorised Signatory

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR NATWEST

GROUP PENSION FUND (MAIN FUND SECTION),

as Lender

By:   /s/ Cameron Price
Name: Cameron Price
Title: Authorised Signatory
By:   /s/ Nick Cleary
Name: Nick Cleary
Title: Authorised Signatory

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NOMURA CORPORATE FUNDING AMERICAS, LLC,

as Lender

By:   /s/ Vinod Mukani
Name: Vinod Mukani
Title: Managing Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

Project and Trade Finance Core Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

RAYMOND JAMES BANK,

as Lender

By:   /s/ Robert F. Moyle
Name: Robert F. Moyle
Title: Managing Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

RIN II Ltd.

RIN III Ltd.

RIN IV Ltd.

RIN V Ltd.

RIN VI Ltd.,

as Lender

By:   /s/ Joshua Mintz
Name: Joshua Mintz
Title: Authorized Signatory
By:   /s/ Cameron Berns
Name: Cameron Berns
Title: Authorized Signatory

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

ROYAL BANK OF CANADA,

as Lender

By:   /s/ Michael Sharp
Name: Michael Sharp
Title: Authorized Signatory

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

SPT INFRASTRUCTURE FINANCE SUB-4 LLC,

as Lender

By:   /s/ Sean Musdock
Name: Sean Musdock
Title: Managing Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

SUMITOMO MITSUI BANKING CORPORATION,

as Lender

By:   /s/ Brian T. Caldwell
Name: Brian T. Caldwell
Title: Brian T. Caldwell

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

THE BANK OF NOVA SCOTIA, HOUSTON BRANCH,

as Lender

By:   /s/ Joe Lattanzi
Name: Joe Lattanzi
Title: Managing Director

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

BANCO DE SABADELL, S.A., MIAMI BRANCH,

as Lender

By:   /s/ Ignacio Alcaraz
Name: Ignacio Alcaraz
Title: Head of Structured Finance Americas

 

SIGNATURE PAGE TO FOURTH AMENDMENT TO THE CTA AND SECOND

AMENDMENT TO THE CFA

Exhibit 10.79

Execution Version

FIFTH AMENDMENT TO THE COMMON TERMS AGREEMENT AND THIRD

AMENDMENT TO THE COMMON SECURITY AND ACCOUNT AGREEMENT

This FIFTH AMENDMENT TO THE COMMON TERMS AGREEMENT AND THIRD AMENDMENT TO THE COMMON SECURITY AND ACCOUNT AGREEMENT (this “Amendment”), dated as of February 27, 2023 (the “Effective Date”), is in respect of (a) the Common Terms Agreement, dated as of August 19, 2019, by and among Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Borrower”), TransCameron Pipeline, LLC (the “Guarantor”), Natixis, New York Branch, as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties (in such capacity, the “Credit Facility Agent”), each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Mizuho Bank, Ltd., as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”), as amended by that certain Consent and Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of December 28, 2020, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, that certain Second Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of January 26, 2021, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, that certain Third Amendment to the Common Terms Agreement, First Amendment to the Common Security and Account Agreement and Consent to the Credit Facility Agreement, dated as of May 25, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, Mizuho Bank (USA), as Collateral Agent (in such capacity, the “Collateral Agent”) and Intercreditor Agent, and that certain Fourth Amendment to the Common Terms Agreement and Second Amendment to the Credit Facility Agreement (the “Fourth CTA Amendment”), dated as of October 12, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”) and (b) the Common Security and Account Agreement, dated as of August 19, 2019, by and among the Borrower, the Guarantor, the Senior Creditor Group Representatives from time to time party thereto, the Intercreditor Agent, the Collateral Agent and Mizuho Bank, Ltd., as the account bank, as amended by that certain Third Amendment to the Common Terms Agreement, First Amendment to the Common Security and Account Agreement and Consent to the Credit Facility Agreement, dated as of May 25, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, the Collateral Agent and Intercreditor Agent, and that certain Second Amendment to the Common Security and Account Agreement (the “Second CSAA Amendment”), dated as of January 9, 2023, by and among Borrower, Guarantor, the Collateral Agent and Intercreditor Agent (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Common Security and Account Agreement”). All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Common Terms Agreement. For all purposes of this Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.

WHEREAS, the Fourth CTA Amendment modified the definition of “Date Certain” in the Common Terms Agreement.


WHEREAS, the Second CSAA Amendment modified the definition of “Date Certain” in the Common Security and Account Agreement to match the definition of “Date Certain” in the Common Terms Agreement.

WHEREAS, the Borrower has requested that the Credit Facility Lenders under the Credit Facility Agreement (collectively, the “Lenders” and each individually, a “Lender”), the Credit Facility Agent, the Collateral Agent and the Intercreditor Agent consent and agree to (i) amend the Common Terms Agreement and the Common Security and Account Agreement and (ii) waive the timely delivery of the certificate required by Section 11.3(j) of the Common Terms Agreement on the terms and conditions set forth herein and in accordance with Section 23.15 of the Common Terms Agreement, Section 4 of the Intercreditor Agreement, Section 7.2(a)(i)(A) (Modification Approval Levels) and 12.14 (Amendments) of the Common Security and Account Agreement.

NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1. Consents and Amendments.

1.1 Consents and Amendments to Common Terms Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, each of the Lenders party hereto, the Credit Facility Agent (at the direction of Required Lenders) and the Intercreditor Agent hereby consent and agree as follows:

(a) The definition of “Date Certain” in Section 1.3 (Definitions) of Schedule A (Common Definitions and Rules of Interpretation) to the Common Terms Agreement shall be amended and restated in its entirety as follows:

““Date Certain” means January 31, 2024 provided that if, on or prior to January 31, 2024, the Borrower certifies to the Intercreditor Agent (and the Independent Engineer reasonably concurs with such certification in writing) that (i) the only remaining condition to the Project Completion Date as of the date of delivery of such certification, other than conditions that can only be satisfied on the Project Completion Date, is the condition specified in Section 14.1(c)(iii) (Conditions to Occurrence of the Project Completion Date – Physical Completion Certificate) and (ii) the Lenders’ Reliability Test has commenced in accordance with the procedures specified in Section 12.11 (Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages) and is reasonably expected to be completed on or prior to April 30, 2024, then for all purposes under this Agreement the “Date Certain” means April 30, 2024.”

 

2


(b) Solely with respect to any Restricted Payment made pursuant to Section 11.3 (Pre-Completion Restricted Payments) of the Common Terms Agreement between the date hereof and March 3, 2023, the Borrower shall be permitted to deliver the certificate required by Section 11.3(j) (Pre-Completion Restricted Payments) of the Common Terms Agreement on the date of such Restricted Payment (in lieu of delivery at least two Business Days prior to the date of such Restricted Payment).

1.2 Administrative Amendment to Common Security and Account Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, the Collateral Agent (at the direction of the Intercreditor Agent) hereby consents and agrees to amend the Common Security and Account Agreement as follows:

““Date Certain” means January 31, 2024 provided that if, on or prior to January 31, 2024, the Borrower certifies to the Intercreditor Agent (and the Independent Engineer reasonably concurs with such certification in writing) that (i) the only remaining condition to the Project Completion Date as of the date of delivery of such certification, other than conditions that can only be satisfied on the Project Completion Date, is the condition specified in Section 14.1(c)(iii) (Conditions to Occurrence of the Project Completion Date – Physical Completion Certificate) and (ii) the Lenders’ Reliability Test has commenced in accordance with the procedures specified in Section 12.11 (Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages) and is reasonably expected to be completed on or prior to April 30, 2024, then for all purposes under this Agreement the “Date Certain” means April 30, 2024.”

Section 2. Effectiveness. This Amendment shall become effective as of the date hereof subject to satisfaction of the following conditions precedent:

2.1 delivery of executed counterparts of this Amendment by each of (i) the Borrower, (ii) the Guarantor, (iii) the Intercreditor Agent, (iv) the Collateral Agent, (v) the Credit Facility Agent (who constitutes the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement)) and (vi) Lenders constituting the Required Lenders under the Credit Facility Agreement;

2.2 the Intercreditor Agent and the Credit Facility Agent shall have received an updated Construction Budget and Schedule;

2.3 the Intercreditor Agent and the Credit Facility Agent shall have received a certificate from the Borrower certifying that:

(a) since the last delivery by the Independent Engineer of the monthly construction report as provided by Section 10.4 (Construction Reports) of the Common Terms Agreement, the Borrower has not become aware of any event or circumstance the occurrence of which could reasonably be expected to (i) increase the total Project Costs materially above those set forth in the Construction Budget and Schedule (as updated pursuant to Section 2.2), or (ii) have a Material Adverse Effect;

 

3


(b)

(i) the sum of (A) amounts on deposit in the Contingency Reserve Account, (B) amounts on deposit in the Construction Account, (C) amounts on deposit in the Pre-Completion Revenues Account, and (D) the amounts of any committed, but undrawn, Senior Debt Commitment available to the Borrower equals or exceeds

(ii) the amount of funds that are, as of the date hereof, reasonably required to achieve the Project Completion Date (excluding any amounts required to be funded in the Senior Facilities Debt Service Reserve Account and each other Additional Debt Service Reserve Account (if any) (or, if the Senior Facilities Debt Service Reserve Account or any such Additional Debt Service Reserve Account is not yet required to be funded, the amount that will be required to be funded therein on the first date on which such account is required to be funded)) by the Date Certain (as amended by this Amendment) (such amount in this clause (ii), the “Required Completion Amount”);

(c) the Borrower reasonably believes that Project Completion Date shall occur on or prior to the Date Certain (as amended by this Amendment).

2.4 the Borrower has delivered to the Intercreditor Agent a certification from the Independent Engineer confirming (a) that it reasonably expects the Project Completion Date to be achieved by the Date Certain (as amended by this Amendment) and (b) the Obligors have funds equal to or in excess of the Required Completion Amount.

Section 3. Representations and Warranties. Each of the Obligors hereby represents and warrants to the Lenders, Credit Facility Agent, the Collateral Agent and Intercreditor Agent that:

3.1 upon the effectiveness of the consents and amendments set forth in Section 1, no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing or will result from the consummation of the transactions contemplated by this Amendment; and

3.2 upon the effectiveness of the consents and amendments set forth in Section 1, each of the representations and warranties of the Obligors in the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents is true and correct in all material respects except (A) for those representations and warranties that are qualified by materiality, which are true and correct in all respects on and as of the date hereof (or, if stated to have been made solely as of an earlier date, as of such earlier date) and (B) for the representations and warranties set forth in Section 5.1 (Initial Representations and Warranties of the Obligors) of the Common Terms Agreement, which were made only on the Closing Date.

Section 4. Finance Document. This Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement. Each of the parties hereto agree that (i) each reference to “Common Terms Agreement” in each Finance Document, including the Intercreditor Agreement and the Common Security and Account Agreement, shall refer to the Common Terms Agreement as amended hereby and (ii) each reference to “Common Security and Account Agreement” in each Finance Document, including the Intercreditor Agreement and the Common Terms Agreement, shall refer to the Common Security and Account Agreement as amended hereby.

 

4


Section 5. Governing Law. THIS AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA.

Section 6. Headings. All headings in this Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.

Section 7. Binding Nature and Benefit; Amendment. This Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 8. Counterparts. This Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Amendment.

Section 9. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Common Terms Agreement, the Common Security and Account Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Amendment apply to any other matters.

Section 10. E-Signature. The words “execution,” “signed,” “signature,” and words of like import in this Amendment shall be deemed to include electronic signatures or electronic records, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any legal requirements, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

Section 11. Direction to Credit Facility Agent, Intercreditor Agent and Collateral Agent.

11.1 By their signature below, each of the undersigned Credit Facility Lenders (collectively constituting the Required Lenders) instructs the Credit Facility Agent to (i) execute this Amendment and (ii) direct the Intercreditor Agent to execute this Amendment.

 

5


11.2 Based on the instructions in Section 11.1, the Credit Facility Agent, constituting the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement), hereby directs the Intercreditor Agent to execute this Amendment.

11.3 The Borrower hereby confirms that the amendment contemplated in Section 1.2 is an Administrative Decision within the meaning of Schedule 2 to the Intercreditor Agreement and hereby requests that the Intercreditor Agent provide a direction to the Collateral Agent in accordance with Section 7.2(a)(i)(A) (Modification Approval Levels) and 12.14 (Amendments) of the Common Security and Account Agreement to execute this Amendment.

11.4 Based on the certification in Section 11.3, the Intercreditor Agent hereby directs the Collateral Agent to execute this Amendment.

[Remainder of the page left intentionally blank.]

 

6


IN WITNESS WHEREOF, the Parties have caused this Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as the Borrower

By:

 

/s/ Jonathan W. Thayer

Name: Jonathan W. Thayer

Title: Chief Financial Officer

TRANSCAMERON PIPELINE, LLC,

as the Guarantor

By:

 

/s/ Jonathan W. Thayer

Name: Jonathan W. Thayer

Title: Chief Financial Officer

 

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

By:   /s/ Lisa Wong
Name: Lisa Wong
Title: Director
By:   /s/ Frederic Bouley
Name: Frederic Bouley
Title: Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Intercreditor Agent

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title: Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK (USA),

as Collateral Agent

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title: Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

Royal Bank of Canada,

as Lender

By:   /s/ Jason S. York
Name: Jason S. York
Title: Authorized Signatory

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR THE NATWEST GROUP PENSION FUND (MAIN FUND SECTION),

as Lender

By:   /s/ Lisa Shaw
Name: Lisa Shaw
Title: Attorney
By:   /s/ Jinny Hwang
Name: Jinny Hwang
Title: Attorney

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR THE NATWEST GROUP PENSION FUND (AA SECTION),

as Lender

By:   /s/ Lisa Shaw
Name: Lisa Shaw
Title: Attorney
By:   /s/ Jinny Hwang
Name: Jinny Hwang
Title: Attorney

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

National Bank of Canada,

as Lender

By:   /s/ Mark Williamson
Name: Mark Williamson
Title: Managing Director & Head of Energy Project Finance
By:   /s/ John Hunt
Name: John Hunt
Title: Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

RIN II Ltd.

 

RIN III Ltd.

 

RIN IV Ltd.

 

RIN V Ltd.

 

RIN VI Ltd,

as Lender

By:   /s/ Joshua Mintz
Name: Joshua Mintz
Title: Authorized Signatory
By:   /s/ Matt Woods
Name: Matt Woods
Title: Authorized Signatory

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

Federated Hermes Project and Trade Finance Master Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.
Federated Hermes Project and Trade Finance Tender Fund, as Lender
By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

Project and Trade Finance Core Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

LANDESBANK BADEN-WÜRTTEMBERG

as Lender

By:   /s/ Oliver Langel
Name: Oliver Langel
Title: Executive Director
By:   /s/ Arndt Bruns
Name: Arndt Bruns
Title: Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

SUMITOMO MITSUI BANKING CORPORATION,

as Lender

By:   /s/ Brian Caldwell
Name: Brian Caldwell
Title: Managing Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

SPT INFRASTRUCTURE FINANCE SUB-4, LLC,

as Lender

By:   /s/ Haig Najarian
Name: Haig Najarian
Title: Authorized Signatory

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

WOORI GLOBAL INFRASTRUCTURE SYNERGY-UP FUND,

as Lender

By:   /s/ Park Joon Hyung
Name: Park Joon Hyung
Title: Manager

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA

 

   LOGO


Acknowledged and agreed as of the first date set forth above.

THE BANK OF NOVA SCOTIA, HOUSTON BRANCH,

as Lender

By:   /s/ Joe Lattanzi
Name: Joe Lattanzi
Title: Managing Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

BANCO DE SABADELL, S.A., MIAMI

BRANCH, as Lender

By:   /s/ Enrique Castillo
Name: Enrique Castillo
Title: Head of Corporate Banking

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

ING Capital LLC,

as Lender

By:   /s/ Subha Pasumarti
Name: Subha Pasumarti
Title: Managing Director
By:   /s/ Paul Mandeville
Name: Paul Mandeville
Title: Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

Goldman Sachs Bank USA,

as Lender

By:   /s/ Keshia Leday
Name: Keshia Leday
Title: Authorized Signatory

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

BANCO SANTANDER, S.A., NEW YORK BRANCH,

as Lender

By:   /s/ Daniel S Kostman
Name: Daniel S Kostman
Title: ED
By:   /s/ Robert Cestari
Name: Robert Cestari
Title: ED

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

LANDESBANK HESSEN-THÜRINGEN GIROZENTRALE, NEW YORK BRANCH,

as Lender

By:   /s/ David A. Leech
Name: David A. Leech
Title: Senior Vice President
By:   /s/ Raf Goebel
Name: Raf Goebel
Title: Vice President

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

Natixis, New York Branch,

as Lender

By:   /s/ Anthony Perna
Name: Anthony Perna
Title: Director
By:   /s/ Alejandro Campos
Name: Alejandro Campos
Title: Executive Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

CaixaBank,

as Lender

By:   /s/ Maria Luisa Cobos
Name: Maria Luisa Cobos
Title: Attorney
By:   /s/ Miguel Rueda
Name: Miguel Rueda
Title: Attorney

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

BANK OF AMERICA, N.A.

as Lender

By:   /s/ Ronald E. McKaig
Name: Ronald E. McKaig
Title: Managing Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

First-Citizens Bank & Trust Company

as Lender

By:   /s/ Stephen Norcross
Name: Stephen Norcross
Title: Vice President

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

BAYERISCHE LANDESBANK, NEW YORK BRANCH,

as Lender

By:   /s/ Andrew Kjoller
Name: Andrew Kjoller
Title: Executive Vice President
By:   /s/ Elke Videgain
Name: Elke Videgain
Title: Vice President

 

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

FIRSTBANK PUERTO RICO d/b/a FIRSTBANK FLORIDA,

as Lender

By:   /s/ Kevin P. Flynn
Name: Kevin P. Flynn
Title: SVP, Corporate Banking Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Lender

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title: Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


NOMURA CORPORATE FUNDING AMERICAS, LLC,

as Lender

By:   /s/ Vinod Mukani
Name: Vinod Mukani
Title: Managing Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

BASISGV/PX (Investments) Ltd.,

as Lender

By:   /s/ Laurie Harding
Name: Laurie Harding
Title: Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

JPMorgan Chase Bank, N.A.,

as Lender

By:   /s/ Arina Mavilian
Name: Arina Mavilian
Title: Executive Director

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

KfW IPEX-Bank GmbH,

as Lender

By:   /s/ Carsten Krecke
Name: Carsten Krecke
Title: Vice President
By:   /s/ Dr. Andreas Kittner
Name: Dr. Andreas Kittner
Title: Director

 

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MUNICH REINSURANCE AMERICA, INC.,

as Lender

By:   /s/ Oliver J. Horbelt
Name: Oliver J. Horbelt
Title: Senior Vice President and Chief Financial Officer
By:   /s/ Ganesh Narayan
Name: Ganesh Narayan
Title: Vice President & Controller

 

 

SIGNATURE PAGE TO FIFTH AMENDMENT TO THE CTA AND THIRD AMENDMENT

TO THE CSAA

Exhibit 10.80

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

THIRD AMENDMENT TO THE CREDIT FACILITY AGREEMENT

This THIRD AMENDMENT TO THE CREDIT FACILITY AGREEMENT (this “Amendment”), dated as of May 26, 2023 (the “Effective Date”), is in respect of the Credit Facility Agreement, dated as of August 19, 2019, by and among Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Borrower”), TransCameron Pipeline, LLC (the “Guarantor”), the Lenders party thereto from time to time, the Issuing Banks party thereto from time to time, Natixis, New York Branch, as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties (in such capacity, the “Credit Facility Agent”), and solely for purposes of Section 3.06 thereof, Mizuho Bank (USA), as Collateral Agent (in such capacity, the “Collateral Agent”), as amended by that certain Consent and Amendment to Credit Facility Agreement, dated as of September 30, 2021, by and among the Borrower, the Guarantor, Calcasieu Pass Pledgor, LLC, as pledgor, the Credit Facility Agent and the Incremental Lender/Issuing Banks party thereto, and that certain Second Amendment to the Credit Facility Agreement (the “Fourth CTA Amendment”), dated as of October 12, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Credit Facility Agreement”). In addition, reference is made to the Common Terms Agreement, dated as of August 19, 2019, by and among the Borrower, the Guarantor, the Credit Facility Agent, each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Mizuho Bank, Ltd., as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”), as amended by that certain Consent and Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of December 28, 2020, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, that certain Second Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of January 26, 2021, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, that certain Third Amendment to the Common Terms Agreement, First Amendment to the Common Security and Account Agreement and Consent to the Credit Facility Agreement, dated as of May 25, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, the Collateral Agent and Intercreditor Agent, that certain Fourth Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement (the “Fourth CTA Amendment”), dated as of October 12, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, and that certain Fifth Amendment to the Common Terms Agreement and Third Amendment to the Common Security and Account Agreement, dated as of February 27, 2023, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”). All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Common Terms Agreement, or if not defined therein, the Credit Facility Agreement. For all purposes of this Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.


WHEREAS, the supervisor for the administrator of LIBOR or a Governmental Entity has made a public statement identifying a specific date after which LIBOR shall no longer be used for determining interest rates for loans;

WHEREAS, in connection with the foregoing, the Borrower has requested that the Credit Facility Agent consent and agree, and the Credit Facility Agent is willing to consent and agree, to amend the Credit Facility Agreement, as applicable, on the terms and conditions set forth herein and in accordance with Section 5.07 of the Credit Facility Agreement.

NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1. Consent and Amendments. Upon the later to occur of (x) the effectiveness of this Amendment in accordance with Section 2 below and (y) the expiration of the existing Interest Period of the Borrower based on LIBOR (May 31, 2023), the Borrower and the Credit Facility Agent hereby consent and agree that the Credit Facility Agreement is hereby amended to delete the red or green stricken text (indicated textually in the same manner as the following examples: stricken text and stricken text) and to add the blue double-underlined text or green underlined text (indicated textually as the following examples: double-underlined text and underlined text), as set forth in the pages of the Credit Facility Agreement attached as Exhibit A hereto.

Section 2. Effectiveness. This Amendment shall become effective as of the date hereof subject to satisfaction of the following conditions precedent:

2.1 delivery of executed counterparts of this Amendment by each of (i) the Borrower and (ii) the Credit Facility Agent (who constitute the requisite parties to effectuate a Benchmark Replacement under Section 5.07 (Benchmark Replacement) of the Credit Facility Agreement);

2.2 a draft of this Amendment shall have been made available to all Lenders (including by posting to a datasite to which such Lenders have access) at least five (5) Business Days prior to the date hereof; and

2.3 the Credit Facility Agent shall not have received written notice of objection to the entry by the Credit Facility Agent into this Amendment from the Required Lenders prior to the date hereof.

Section 3. Representations and Warranties. Each of the Obligors hereby represents and warrants to the Lenders, Credit Facility Agent and Intercreditor Agent that:

3.1 upon the effectiveness of the consents and amendments set forth in Section 1, no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing or will result from the consummation of the transactions contemplated by this Amendment; and

 

2


3.2 upon the effectiveness of the consents and amendments set forth in Section 1, each of the representations and warranties of the Obligors in the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents is true and correct in all material respects except (A) for those representations and warranties that are qualified by materiality, which are true and correct in all respects on and as of the date hereof (or, if stated to have been made solely as of an earlier date, as of such earlier date) and (B) for the representations and warranties set forth in Section 5.1 (Initial Representations and Warranties of the Obligors) of the Common Terms Agreement, which were made only on the Closing Date.

Section 4. Finance Document. This Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement. Each of the parties hereto agree that each reference to “Credit Facility Agreement” in each Finance Document, including the Intercreditor Agreement and the Common Terms Agreement, shall refer to the Credit Facility Agreement as amended hereby.

Section 5. Governing Law. THIS AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA.

Section 6. Headings. All headings in this Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.

Section 7. Binding Nature and Benefit; Amendment. This Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 8. Counterparts. This Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Amendment.

Section 9. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Amendment apply to any other matters.

 

3


Section 10. E-Signature. The words “execution,” “signed,” “signature,” and words of like import in this Amendment shall be deemed to include electronic signatures or electronic records, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any legal requirements, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

[Remainder of the page left intentionally blank.]

 

4


IN WITNESS WHEREOF, the Parties have caused this Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as the Borrower

By:   /s/ Leah Woodward
Name: Leah Woodward
Title: Treasurer

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CFA


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

By:   /s/ Lisa Wong
Name: Lisa Wong
Title: Director
By:   /s/ Urs Fischer
Name: Urs Fischer
Title: Executive Director

 

SIGNATURE PAGE TO THIRD AMENDMENT TO THE CFA


Exhibit A

Conformed Through SecondThird Amendment

 

 

CREDIT FACILITY AGREEMENT

 

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as Borrower,

 

 

TRANSCAMERON PIPELINE, LLC,

as Guarantor,

 

 

THE LENDERS PARTY HERETO FROM TIME TO TIME,

as Lenders,

THE ISSUING BANKS HERETO FROM TIME TO TIME,

as Issuing Banks,

and

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

and

solely for purposes of Section 3.06,

MIZUHO BANK (USA),

as Collateral Agent

 

 

Dated as of August 19, 2019


TABLE OF CONTENTS

 

     Page  

ARTICLE I DEFINITIONS AND INTERPRETATION

     2  

Section 1.01

  Defined Terms      2  

Section 1.02

  Principles of Interpretation      2  

Section 1.03

  UCC Terms      2  

Section 1.04

  Accounting and Financial Determinations      2  

Section 1.05

  Designations      2  

Section 1.06

  Rates      2  

ARTICLE II COMMITMENTS AND ADVANCES

     3  

Section 2.01

  Term Loans      3  

Section 2.02

  Term Loan Availability      4  

Section 2.03

  Working Capital Loans      45  

Section 2.04

  Working Capital Loan Availability      6  

Section 2.05

  Procedures for Requesting Advances      7  

Section 2.06

  Funding      9  

Section 2.07

  Termination or Reduction of Commitments      1011  

Section 2.08

  [Reserved]      12  

Section 2.09

  Incremental Commitments      12  

Section 2.10

  Use of Proceeds      14  

ARTICLE III LETTERS OF CREDIT

     15  

Section 3.01

  Letters of Credit      15  

Section 3.02

  Reimbursement to Issuing Banks      1718  

Section 3.03

  Obligations Absolute      1920  

Section 3.04

  Liability of the Issuing Banks and the Working Capital Lenders.      21  

Section 3.05

  Resignation as an Issuing Bank      22  

Section 3.06

  Non-Fronted Letters of Credit      2122  

Section 3.07

  Reinstatement of Letters of Credit      2122  

ARTICLE IV REPAYMENTS, PREPAYMENTS, INTEREST AND FEES

     23  

Section 4.01

  Repayment of Term Loan Advances      23  

Section 4.02

  Repayment of LC Loans      2223  

Section 4.03

  Repayment of Working Capital Advances      2224  

Section 4.04

  Interest Payment Dates      24  

Section 4.05

  Interest Rates      2325  

Section 4.06

  Conversion Options      2426  

Section 4.07

  Post-Maturity Interest Rates; Default Interest Rates      26  

Section 4.08

  Interest Rate Determination      2526  

Section 4.09

  Computation of Interest and Fees      2527  

Section 4.10

  Terms of All Prepayments      2527  

 

i


Section 4.11

  Voluntary Prepayment      2628  

Section 4.12

  Mandatory Prepayment      28  

Section 4.13

  Time and Place of Payments      2729  

Section 4.14

  Advances and Payments Generally      2830  

Section 4.15

  Fees      2830  

Section 4.16

  Pro Rata Treatment      3032  

Section 4.17

  Sharing of Payments      3132  

Section 4.18

  Defaulting Lenders      3133  

ARTICLE V LIBORSOFR AND TAX PROVISIONS

     3335  

Section 5.01

  LIBOR Lending UnlawfulIllegality      3335  

Section 5.02

  Inability to Determine LIBORApplicable Interest Rate      3436  

Section 5.03

  Increased Costs      3437  

Section 5.04

  Obligation to Mitigate      3538  

Section 5.05

  Funding Losses      3639  

Section 5.06

  Taxes      3640  

Section 5.07

  Effect ofReplacement Benchmark Transition EventSetting      3640  

ARTICLE VI REPRESENTATIONS AND WARRANTIES

     3741  

Section 6.01

  Incorporation of Common Terms Agreement      3741  

ARTICLE VII CONDITIONS PRECEDENT

     3742  

Section 7.01

  Conditions to Closing      3742  

Section 7.02

  Conditions to Each Term Loan Advance      3842  

Section 7.03

  Conditions to Each Working Capital Advance      3842  

Section 7.04

  Conditions to Occurrence of the Project Completion Date      3842  

ARTICLE VIII COVENANTS

     3843  

Section 8.01

  Covenants      3843  

ARTICLE IX DEFAULT AND ENFORCEMENT

     3943  

Section 9.01

  Events of Default      3943  

Section 9.02

  Acceleration Upon Bankruptcy      3943  

Section 9.03

  Action Upon Event of Default      3943  

Section 9.04

  Cash Collateralization of Letters of Credit      4045  

Section 9.05

  Application of Proceeds      4145  

ARTICLE X THE CREDIT FACILITY AGENT

     4145  

Section 10.01

  Appointment and Authority      4145  

Section 10.02

  Rights as a Facility Lender or Hedging Bank      4246  

Section 10.03

  Exculpatory Provisions      4247  

Section 10.04

  Reliance by Credit Facility Agent      4448  

 

ii


Section 10.05

  Delegation of Duties      4549  

Section 10.06

  Indemnification by the Lenders      4549  

Section 10.07

  Resignation or Removal of Credit Facility Agent      4650  

Section 10.08

  No Amendment to Duties of Credit Facility Agent Without Consent      4752  

Section 10.09

  Non-Reliance on Credit Facility Agent, Lenders      4752  

Section 10.10

  No Initial Coordinating Lead Arranger, Coordinating Lead Arranger or Documentation Bank Duties      4852  

Section 10.11

  Copies      4852  

Section 10.12

  General Provisions as to Payments      4852  

Section 10.13

  Agreement to Comply with Finance Documents      4953  

ARTICLE XI MISCELLANEOUS PROVISIONS

     4953  

Section 11.01

  Decisions; Amendments, Etc.      4953  

Section 11.02

  Entire Agreement      5257  

Section 11.03

  Applicable Government Rule; Jurisdiction; Etc.      5257  

Section 11.04

  Assignments      5357  

Section 11.05

  Benefits of Agreement      5964  

Section 11.06

  Counterparts; Effectiveness      5964  

Section 11.07

  Indemnification by the Borrower      5964  

Section 11.08

  Interest Rate Limitation      6065  

Section 11.09

  No Waiver; Cumulative Remedies      6065  

Section 11.10

  Notices and Other Communications      6165  

Section 11.11

  USA Patriot Act Notice      6166  

Section 11.12

  Payments Set Aside      6266  

Section 11.13

  Right of Set-Off      6267  

Section 11.14

  Severability      6267  

Section 11.15

  Survival      6267  

Section 11.16

  Treatment of Certain Information; Confidentiality      6367  

Section 11.17

  Waiver of Consequential Damages, Etc.      6368  

Section 11.18

  Waiver of Litigation Payments      6368  

Section 11.19

  Reinstatement      6368  

Section 11.20

  No Recourse      6468  

Section 11.21

  Intercreditor Agreement      6468  

Section 11.22

  Termination      6469  

Section 11.23

  Acknowledgment and Consent to Bail-In of EEA Financial Institutions      6469  

SCHEDULES

 

Schedule I

- Lenders, Commitments

Schedule II

- Issuing Bank Limits

Schedule III

- Amortization Schedule

Schedule IV

- Credit Facility Agent Account Details

 

iii


EXHIBITS

 

Exhibit A

- Definitions

Exhibit B-1

- Form of Term Loan Note

Exhibit B-2

- Form of Working Capital Note Exhibit C - [Reserved]

Exhibit D

- [Reserved]

Exhibit E-1

- Form of Letter of Credit – TETCO

Exhibit E-2

- Form of Letter of Credit – ANR

Exhibit E-3

- Form of Letter of Credit – EnLink

Exhibit F

- Form of Interest Period Notice

Exhibit G

- Form of Lender Assignment Agreement

 

iv


CREDIT FACILITY AGREEMENT

This CREDIT FACILITY AGREEMENT, dated as of August 19, 2019 (the “Credit Facility Agreement” or this “Agreement”), is made among:

VENTURE GLOBAL CALCASIEU PASS, LLC, a limited liability company organized under the laws of the State of Delaware (the “Borrower”),

TRANSCAMERON PIPELINE, LLC, a limited liability company organized under the laws of the State of Delaware (the “Guarantor”),

NATIXIS, NEW YORK BRANCH, in its capacity as administrative agent for the Lenders and Issuing Banks hereunder (and, together with each other Person that may, from time to time, be appointed as successor Credit Facility Agent in accordance with Section 10.07 (Resignation or Removal of Credit Facility Agent), the “Credit Facility Agent”),

Solely for purposes of Section 3.06, MIZUHO BANK (USA), as the Collateral Agent (the “Collateral Agent”),

Each of the Issuing Banks party hereto from time to time, and

Each of the Lenders party hereto from time to time.

WHEREAS, the Borrower intends to engage in the Development;

WHEREAS, the Borrower has requested that (i) the Working Capital Lenders and the Issuing Banks establish a working capital credit facility in order to provide loans and letters of credit which are to be used by, or otherwise be issued for the account of, the Obligors, as set forth herein and in the other Finance Documents (the “Working Capital Facility”) and (ii) the Term Lenders establish a credit facility in order to provide funds which are to be used to partially finance the Development through the payment of Project Costs and otherwise, as set forth herein and in the other Finance Documents;

WHEREAS, pursuant to that certain Assignment of Intercompany Loan Agreement, dated as of the date hereof, by and between the Borrower, the Guarantor, the Sponsor and the Credit Facility Agent, the Sponsor has assigned to the Credit Facility Agent all of its right, title and interest in and to that certain Intercompany Loan Agreement, dated as of March 29, 2019, by and between the Sponsor, as lender, and the Borrower, as Borrower (the “Intercompany Loan Agreement”), and the loans to the Borrower made thereunder in the principal amount of up to $150,000,000; and

WHEREAS, the Borrower, the Guarantor, the Credit Facility Agent, Working Capital Lenders, the Issuing Banks, the Term Lenders and, solely for purposes of Section 3.06 hereof, desire to amend and restate the Intecompany Loan Agreement to make such credit facilities available upon and subject to the terms and conditions hereinafter set forth.


NOW THEREFORE, in consideration of the foregoing, and for other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, the parties hereto hereby amend and restate the Intercompany Loan Agreement in its entirety and agree as follows:

ARTICLE I

DEFINITIONS AND INTERPRETATION

Section 1.01 Defined Terms. Unless otherwise defined in Exhibit A, capitalized terms used in this Agreement (including the preamble hereto) shall have the meanings provided in Section 1.3 (Definitions) of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement.

Section 1.02 Principles of Interpretation. Unless otherwise provided herein, this Agreement shall be governed by the principles of interpretation provided in Section 1.2 (Interpretation) of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement, mutatis mutandis.

Section 1.03 UCC Terms. Unless otherwise defined herein or in Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement, terms used herein that are defined in the UCC shall have the respective meanings given to those terms in the UCC.

Section 1.04 Accounting and Financial Determinations. Except as otherwise expressly provided herein, all terms of an accounting or financial nature shall be construed in accordance with GAAP, as in effect from time to time; provided, that, if the Borrower notifies the Intercreditor Agent and the Credit Facility Agent that the Borrower requests an amendment to any provision hereof to eliminate the effect of any change occurring after the Closing Date in GAAP or in the application thereof on the operation of, or calculation of compliance with, such provision so as to preserve the original intent thereof in light of such change in GAAP (or if the Intercreditor Agent and Credit Facility Agent, as the case may be, notifies the Borrower that the Required Lenders request an amendment to any provision hereof for such purpose), regardless of whether any such notice is given before or after such change in GAAP or in the application thereof, then such provision shall be interpreted on the basis of GAAP as in effect and applied immediately before such change shall have become effective until such provision has been amended in accordance herewith.

Section 1.05 Designations. This Agreement is a Facility Agreement and a Senior Debt Instrument, the Term Lenders, Working Capital Lenders and Issuing Banks in this Agreement are Senior Creditors and the Credit Facility Agent is the Senior Creditor Group Representative of the Term Lenders, the Working Capital Lenders and the Issuing Banks, in each case under the Finance Documents.

Section  1.06 Rates. The Credit Facility Agent does not warrant or accept responsibility for, and shall not have any liability with respect to (a) the continuation of, administration of, submission of, calculation of or any other matter related to the Base Rate, the Term SOFR Reference Rate, Adjusted Term SOFR or Term SOFR, or any component definition thereof or

 

2


rates referred to in the definition thereof, or any alternative, successor or replacement rate thereto (including any Benchmark Replacement), including whether the composition or characteristics of any such alternative, successor or replacement rate (including any Benchmark Replacement) will be similar to, or produce the same value or economic equivalence of, or have the same volume or liquidity as, the Base Rate, the Term SOFR Reference Rate, Adjusted Term SOFR, Term SOFR or any other Benchmark prior to its discontinuance or unavailability, or (b) the effect, implementation or composition of any Conforming Changes. The Credit Facility Agent and its affiliates or other related entities may engage in transactions that affect the calculation of the Base Rate, the Term SOFR Reference Rate, Adjusted Term SOFR, Term SOFR, any alternative, successor or replacement rate (including any Benchmark Replacement) or any relevant adjustments thereto, in each case, in a manner adverse to the Borrower. The Credit Facility Agent may select information sources or services in its reasonable discretion to ascertain the Base Rate, the Term SOFR Reference Rate, Adjusted Term SOFR, Term SOFR or any other Benchmark, in each case pursuant to the terms of this Agreement, and shall have no liability to the Borrower, any Lender or any other person or entity for damages of any kind, including direct or indirect, special, punitive, incidental or consequential damages, costs, losses or expenses (whether in tort, contract or otherwise and whether at law or in equity), for any error or calculation of any such rate (or component thereof) provided by any such information source or service.

ARTICLE II

COMMITMENTS AND ADVANCES

On the terms, subject to the conditions and relying upon the representations and warranties herein set forth:

Section 2.01 Term Loans. (a) Each Term Lender, severally and not jointly, shall make Term Loans to the Borrower: (i) in an aggregate principal amount not in excess of the Base Term Loan Commitments of such Term Lender, if any, from time to time during the Term Loan Availability Period but not more frequently than as permitted under Section 2.05 (Procedures for Requesting Advances) for use in accordance with Section 2.10(a)(i) (Use of Proceeds); and (ii) in an aggregate principal amount not in excess of the Contingency Reserve Term Loan Commitments of such Term Lender, if any, from time to time during the Term Loan Availability Period but not more frequently than as permitted under Section 2.05 (Procedures for Requesting Advances) for use in accordance with Section 2.10(a)(ii) (Use of Proceeds); provided that, after giving effect to the making of any Term Loans, the aggregate outstanding principal amount of all Term Loans shall not exceed the Aggregate Term Loan Commitments. The aggregate amount of the Base Term Loan Commitments as of the Closing Date is $[***], and the aggregate amount of the Contingency Reserve Term Loan Commitments as of the Closing Date is $[***].

 

3


(b) Each Term Loan Advance shall be in an amount specified in the relevant Disbursement Request.

(c) Except as set forth in clause (d) below, proceeds of the Term Loans shall be deposited into the Construction Account in accordance with Section 4.5(a) (Deposits and Withdrawals – Disbursements of Senior Debt) of the Common Security and Account Agreement. The Obligors shall not request or apply any portion of any Term Loan other than in accordance with this Section 2.1 (Term Loans), Sections 2.02 (Term Loan Availability) and 2.10 (Use of Proceeds) of this Agreement and Sections 2.3 (Disbursement Procedures), 2.4 (Pro Rata Advances), 2.6 (Currency) and 12.1 (Use of Proceeds) of the Common Terms Agreement. Neither the Credit Facility Agent nor the Term Lenders are under any obligation hereunder to inquire into or verify the application of any Term Loan but this does not affect or limit the Obligors’ obligations hereunder or under the Common Terms Agreement.

(d) Notwithstanding Section 2.01(c), proceeds of the Term Loans funded from the Contingency Reserve Term Loan Commitment (including as such proceeds may be used to fund the Contingency Reserve Account on the Project Completion Date (as specified in Section 14.2(b) (Project Completion Date Waterfall – Final Advance of Term Loans) of the Common Terms Agreement)) shall be paid into the Contingency Reserve Account in accordance with Section 4.5(k) (Deposits and Withdrawals – Contingency Reserve Account) of the Common Security and Account Agreement; provided that such transfer shall occur on the same day that the Credit Facility Agent receives such proceeds from the Term Lenders and subject to the Credit Facility Agent’s actual receipt of such proceeds in accordance with Section 2.06(a) (Funding). For the avoidance of doubt, such Advances shall constitute a Term Loan for all purposes under this Agreement and each other Finance Document and shall be treated as received, and accounted for as a Term Loan, by the Borrower.

(e) Term Loans that are repaid or prepaid may not be reborrowed.

Section 2.02 Term Loan Availability. (a) Subject to the terms and conditions set forth in this Agreement and the Common Terms Agreement, each Term Lender severally, and not jointly or jointly and severally, agrees to advance to the Borrower its pro rata share of such Term Lender’s Term Loan Commitment as the Borrower may request under this Section 2.02 (Term Loan Availability) and the applicable Disbursement Request (each such Advance when made, individually, a “Term Loan” and, collectively, the “Term Loans”), in an aggregate principal amount not to exceed such Term Lender’s Term Loan Commitment, from time to time during the period commencing (solely with respect to the Initial Advance) on the Closing Date and (with respect to all other Advances of Term Loans) following the utilization in full of both the Closing Date Equity Funding and the Initial Advance, and ending on the earliest of (such period, the “Term Loan Availability Period”):

(i) March 31, 2023;

(ii) the Project Completion Date;

 

4


(iii) the date the Term Loan Commitments are fully utilized or of any cancellation or termination of all of the remaining Term Loan Commitments pursuant to Section 3.8 (Reductions and Cancellations of Facility Commitments) of the Common Terms Agreement; and

(iv) the date the Required Lenders terminate their Commitments upon the occurrence and during the Continuance of a Loan Facility Event of Default.

(b) Subject to Section 2.2 (Sequence of Advances of Initial Senior Debt) of the Common Terms Agreement, Section 2.4 (Pro Rata Advances) of the Common Terms Agreement and the applicable conditions of Article 4 (Conditions Precedent) of the Common Terms Agreement and Section 2.02(a) (Term Loan Availability) of this Agreement, the Borrower shall be entitled to draw down all or a portion of the unused Term Loan Commitments before or on the final date of the Term Loan Availability Period for the purposes set forth in Section 12.1 (Use of Proceeds) of the Common Terms Agreement and Section 2.10 (Use of Proceeds) of this Agreement.

Section 2.03 Working Capital Loans. (a) Each Working Capital Lender, severally and not jointly, shall make Working Capital Loans to the Borrower in an aggregate principal amount not in excess of its Working Capital Commitment from time to time during the Working Capital Loan Availability Period; provided that, after giving effect to the making of any Working Capital Loans, (i) the aggregate Working Capital Commitment Exposure for all Working Capital Lenders shall not exceed the Aggregate Working Capital Commitments and (ii) no Working Capital Lender shall be required to make any Working Capital Loan if such Working Capital Lender’s Working Capital Commitment Exposure would exceed its Working Capital Commitment.

(b) Each Working Capital Advance shall be in an amount specified in the relevant Disbursement Request.

(c) Proceeds of the Working Capital Loans shall be deposited or applied in accordance with Section 4.5(a) (Deposits and Withdrawals – Disbursements of Senior Debt) of the Common Security and Account Agreement. The Obligors shall not request or apply any portion of any Working Capital Loan other than in accordance with this Section 2.03 (Working Capital Loans), Sections 2.04 (Working Capital Loan Availability) and 2.10 (Use of Proceeds) and Section 2.3 (Disbursement Procedures) and Section 2.6 (Currency) of the Common Terms Agreement. Neither the Credit Facility Agent nor the Working Capital Lenders are under any obligation hereunder to inquire into or verify the application of any Working Capital Loan but this does not affect or limit any Obligor’s obligations hereunder or under the Common Terms Agreement.

(d) [Reserved].

 

5


(e) Working Capital Loans repaid or prepaid, except in accordance with Sections 4.12(b)(ii), (iii) and (iv) (Mandatory Prepayment), may be re-borrowed at any time and from time to time up to but excluding the Working Capital Loan Termination Date. Each Working Capital Lender’s Working Capital Commitment shall expire on the Working Capital Loan Termination Date and all other amounts owed hereunder with respect to Working Capital Loans and the Working Capital Commitments shall be paid in full no later than such date.

Section 2.04 Working Capital Loan Availability. (a) Subject to the terms and conditions set forth in this Agreement and the Common Terms Agreement, each Working Capital Lender severally, and not jointly or jointly and severally, agrees to make Advances to the Borrower in the amount of its Commitment Percentage of the amount the Borrower may request, in accordance with this Section 2.04 (Working Capital Loan Availability) and the applicable Disbursement Request (each such Advance, when made, individually, a “Working Capital Loan” and, collectively, the “Working Capital Loans”), in an aggregate principal amount not to exceed such Working Capital Lender’s unused Working Capital Commitment such that its Working Capital Commitment Exposure does not exceed its Working Capital Commitment after giving effect to such Working Capital Loan, from time to time during the period commencing on the Working Capital Loan Availability Date and, in each case, ending on the earliest to occur of the following dates (the “Working Capital Loan Termination Date”) (such period, the “Working Capital Loan Availability Period”):

(i) the Final Maturity Date;

(ii) the date of any cancellation or termination of all of the remaining Working Capital Commitments pursuant to Section 2.07 (Termination or Reduction of Commitments); and

(iii) the date the Working Capital Lenders terminate their Working Capital Commitments upon the occurrence and during the Continuance of a Working Capital Facility Event of Default.

(b) Notwithstanding anything to the contrary in Section 2.04(a) above, including the occurrence of the Working Capital Loan Availability Date, prior to the Project Completion Date, the outstanding aggregate amount of Working Capital Loans at any time shall be no greater than the Pre-Completion Working Capital Loan Sublimit.

(c) Subject to the conditions of Section 2.03 (Working Capital Loans), Section 7.01 (Conditions to Closing) (which incorporates by reference Section 4.1 (Condition to Closing Date and Initial Advance) of the Common Terms Agreement) and Section 7.02 (Conditions to Each Working Capital Advance) of this Agreement (which incorporates by reference Section 4.3 (Condition to Each Advance under the Working Capital Facility) of the Common Terms Agreement), and this Section 2.04 (Working Capital Loan Availability), the Borrower shall be entitled to draw all or a portion of the unused Working Capital Commitments before or on the final date of the Working Capital Availability Period for the purposes set forth in Section 12.1 (Use of Proceeds) of the Common Terms Agreement and Section 2.10(b) (Use of Proceeds).

 

6


Section 2.05 Procedures for Requesting Advances.

(a) From time to time, but no more frequently than twice per calendar month (except as required for the payment of interest or Commitment Fees during the Term Loan Availability Period, and for any draw of remaining Term Loan Commitments on the last day of the Term Loan Availability Period), subject to the limitations set forth in Sections 2.01 (Term Loans), and 2.02 (Term Loan Availability) above and Sections 2.2 (Sequence of Advances of Senior Debt) and 2.4 (Pro Rata Advances) of the Common Terms Agreement, the Borrower may request a Term Loan Advance by delivering to the Credit Facility Agent a properly completed Disbursement Request in accordance with Section 2.3 (Disbursement Procedures) of the Common Terms Agreement and this Section 2.05 (Procedures for Requesting Advances).

(b) The aggregate amount of any proposed Term Loan Advance under this Agreement must be an amount that is no more than the available Term Loan Commitments and not less than $10,000,000 and an integral multiple of $1,000,000 (unless the available Term Loan Commitments are less than $10,000,000). Such Advances shall be made pro rata with respect to other Facility Agreements in accordance with the committed principal amounts under the Term Loan Commitment subject to and in accordance with Section 2.4 (Pro Rata Advances) of the Common Terms Agreement.

(c) From time to time, subject to the limitations set forth in Section 2.03 (Working Capital Loans) and Section 2.04 (Working Capital Loan Availability) above, the Borrower may request a Working Capital Advance by delivering to the Credit Facility Agent a properly completed Disbursement Request in accordance with this Section 2.05 (Procedures for Requesting Advances) and Section 2.3 (Disbursement Procedures) of the Common Terms Agreement. Working Capital Advances under this Agreement may be made concurrently with but shall not be required to be made pro rata with borrowings under any other Facility Agreements. For the avoidance of doubt, Working Capital Advances shall be required to be borrowed pro rata based on each Working Capital Lender’s Commitment Percentage.

(d) The amount of any proposed Working Capital Advance under this Agreement must be an amount that is no more than the unused Aggregate Working Capital Commitments and not less than $5,000,000 and an integral multiple of $1,000,000 (unless the unused Aggregate Working Capital Commitments are less than $5,000,000).

(e) The Credit Facility Agent shall promptly advise each Lender that has a Commitment that is to fund any portion of the Term Loan Advance or Working Capital Advance, as applicable, of any Disbursement Request delivered pursuant to this Section 2.05 (Procedures for Requesting Advances), together with each such Lender’s Commitment Percentage of the requested Advance.

(f) Any Disbursement Request delivered pursuant to clause (a) or (c) above shall be delivered by the Borrower to the Credit Facility Agent by 1:00 p.m. on or before the third (3rd) U.S. Government Securities Business Day prior to the requested Advance Date for the Advance of any LIBORSOFR Loans and 1:00 p.m. on or before the Business Day prior to the requested Advance Date for the Advance of any Base Rate Loans; provided that the notice periods set forth in this clause (f) shall not apply with respect to the Disbursement Request for the Initial Advance, which Disbursement Request may be delivered no later than 11:00 a.m. on the Business Day before the requested Advance Date.

 

7


(g) Each Disbursement Request delivered pursuant to this Section 2.05 (Procedures for Requesting Advances) shall be substantially in the form of Schedule B-1 to the Common Terms Agreement (Disbursement Request Form (Term Loans)) or Schedule B-2 (Disbursement Request Form (Working Capital Loans)). Each such Disbursement Request shall be irrevocable and shall refer to this Agreement and specify:

(i) whether the requested Advance is of Working Capital Loans or Term Loans and, to the extent the requested Advance would constitute Term Loans, whether the requested Advance is to be funded from the Base Term Loan Commitment and/or the Contingency Reserve Term Loan Commitment;

(ii) the requested Advance Date (which shall be a Business Day);

(iii) the amount of such requested Advance (including, where applicable, the amount to be funded from the Base Term Loan Commitment and/or the Contingency Reserve Term Loan Commitment);

(iv) whether the requested Advance is of LIBORSOFR Loans or Base Rate Loans;

(v) in the case of a requested Advance of LIBORSOFR Loans, the Borrower’s election with respect to the duration of the initial Interest Period applicable to such LIBORSOFR Loans, which Interest Period shall be one (1), two (2), three (3), or six (6), nine (9) or twelve (12) months in length; (or, if available to all applicable Lenders, such other periods as may be agreed by the Credit Facility Agent and each Lender (including with respect to the Applicable Margin agreed to by all the Lenders with respect to any such Interest Period));

(vi) if the requested Advance is (A) of a Term Loan, that each of the conditions precedent to such Term Loan Advance has been satisfied or waived in accordance with Section 7.01 (Conditions to Closing) or Section 7.02 (Conditions to Each Term Loan Advance), as applicable, or (B) of a Working Capital Loan, that each of the conditions precedent to such Working Capital Advance has been satisfied or waived in accordance with Section 7.01 (Conditions to Closing) or Section 7.03 (Conditions to Each Working Capital Advance);

(vii) if such Disbursement Request is being made pursuant to Section 2.10(a) or Section 2.10(b) (Use of Proceeds); and

(viii) the wire information of the account to which the proceeds of such Advance are to be deposited.

The currency specified in a Disbursement Request must be US Dollars.

 

8


(h) If no election as to whether the requested Advance is of LIBORSOFR Loans or Base Rate Loans, then the requested Advance shall be of LIBORSOFR Loans; provided that, if the applicable Disbursement Request is delivered to the Credit Facility Agent later than 1:00 p.m. on the third (3rdU.S. Government Securities Business Day prior to the proposed Advance Date, the requested Advance shall be of Base Rate Loans. If no initial Interest Period is specified with respect to any requested LIBORSOFR Loans, then the requested Advance shall be made as a LIBORSOFR Loan with an initial Interest Period of one (1) month.

Section 2.06 Funding. (a) Subject to clause (c) below, on the proposed Advance Date of each Advance, each Lender shall make a Term Loan or a Working Capital Loan, as applicable, in the amount of its Commitment Percentage of such Advance by wire transfer of immediately available funds to the Credit Facility Agent, not later than 1:00 p.m. and the Credit Facility Agent shall transfer and deposit the amounts (i) constituting proceeds of Term Loans so received as set forth in Section 2.01(c) or (d) (Term Loans), as applicable, for application in accordance with Section 4.5(a) (Deposits and Withdrawals – Disbursements of Senior Debt), Section 4.5(c) (Deposits and Withdrawals – Construction Account) and Section 4.5(k) (Deposits and Withdrawals – Contingency Reserve Account) of the Common Security and Account Agreement, as applicable and (ii) constituting proceeds of Working Capital Loans so received as set forth in Section 2.03(c) (Working Capital Loans); provided that, if an Advance does not occur on the proposed Advance Date because any condition precedent to such requested Advance herein specified has not been met, the Credit Facility Agent shall return the amounts so received to each applicable Lender without interest as soon as possible.

(b) Subject to Section 5.04 (Obligation to Mitigate), each Lender may (without relieving the Borrower of its obligation to repay a Loan in accordance with the terms of this Agreement and the Notes), at its option, fulfill its Commitments with respect to any such Loan by causing any domestic or foreign branch or Affiliate of such Lender to make such Loan.

(c) Unless the Credit Facility Agent has been notified in writing by any Lender prior to a proposed Advance Date that such Lender will not make available to the Credit Facility Agent its portion of the Advance proposed to be made on such date, the Credit Facility Agent may assume that such Lender has made such amounts available to the Credit Facility Agent on such date and the Credit Facility Agent in its sole discretion may, in reliance upon such assumption, make available to the Borrower a corresponding amount. If such corresponding amount is not in fact made available to the Credit Facility Agent by such Lender and the Credit Facility Agent has made such amount available to the Borrower the Credit Facility Agent shall be entitled to recover on demand from such Lender such corresponding amount plus interest on such corresponding amount in respect of each day from the date such corresponding amount was made available by the Credit Facility Agent to the Borrower to the date such corresponding amount is recovered by the Credit Facility Agent at an interest rate per annum equal to the Federal Funds Effective Rate. If such Lender pays such corresponding amount (together with such interest), then such corresponding amount so paid shall constitute such Lender’s Term Loan or Working Capital Loan, as applicable, included in such Advance. If such Lender does not pay such corresponding amount forthwith upon the Credit Facility Agent’s demand, the Credit Facility Agent shall promptly notify the Borrower and the Borrower shall promptly repay such corresponding amount to the Credit Facility Agent plus interest on such corresponding amount in respect of each day from the date such corresponding amount was made available by the Credit Facility Agent to the Borrower to the date such corresponding amount is recovered by the Credit Facility Agent at an interest rate per annum equal to the Base Rate plus the Applicable Margin.

 

9


If the Credit Facility Agent receives payment of the corresponding amount from each of the Borrower and such Lender, the Credit Facility Agent shall promptly remit to the Borrower such corresponding amount. If the Credit Facility Agent receives payment of interest on such corresponding amount from each of the Borrower and such Lender for an overlapping period, the Credit Facility Agent shall promptly remit to the Borrower the amount of such interest paid by the Borrower for such period. Nothing herein shall be deemed to relieve any Lender from its obligation to fulfill its Commitments hereunder and, for the avoidance of doubt, a Lender that fails to make its portion of any Advance on the due date for such payment hereunder shall be deemed in default of its obligations under Section 2.01 (Term Loans) or Section 2.03 (Working Capital Loans) above, as applicable. Any payment by the Borrower pursuant to this Section 2.06(c) (Funding) shall be without prejudice to any claim the Borrower may have against a Lender that shall have failed to make such payment to the Credit Facility Agent. The failure of any Lender to make available to the Credit Facility Agent its portion of the Advance shall not relieve any other Lender of its obligations, if any, hereunder to make available to the Credit Facility Agent its portion of the Advance on the date of such Advance, but no Lender shall be responsible for the failure of any other Lender to make available to the Credit Facility Agent such other Lender’s portion of the Advance on the date of any Advance. A notice of the Credit Facility Agent to any Lender or the Borrower with respect to any amounts owing under this Section 2.06(c) (Funding) shall be conclusive, absent manifest error.

(d) Each Lender shall maintain in accordance with its usual practice and form an account or accounts evidencing the Indebtedness of the Borrower to such Lender resulting from each Loan made by such Lender, including the amounts of principal and interest payable and paid to such Lender from time to time hereunder.

(e) The Credit Facility Agent shall maintain at one of the Credit Facility Agent’s offices (i) a copy of any Lender Assignment Agreement delivered to it pursuant to Section 11.04 (Assignments), and (ii) a register for the recordation of (A) the names and addresses of the Lenders and the Issuing Banks, (B) all the Commitments of, and principal amount of and interest on the Loans owing and paid to, each Lender pursuant to the terms hereof from time to time, (C) the amount, beneficiary and termination date of all outstanding Letters of Credit, (D) the Issuing Bank Limit of each Issuing Bank and (E) amounts received by the Credit Facility Agent from the Borrower and whether such amounts constitute principal, interest, fees or other amounts and each Lender’s or Issuing Bank’s share thereof (the “Register”). The Register shall be available for inspection by the Borrower, any Issuing Bank and any Lender (with respect to such Issuing Bank’s Issuing Bank Limits, Fronting Limits and/or Non-Fronting Limits and such Lender’s Commitments and/or Loans, as applicable) at any reasonable time and from time to time upon reasonable prior notice.

(f) The entries made by the Credit Facility Agent in the Register or the accounts maintained by any Lender shall be conclusive and binding evidence, absent manifest error, of the existence and amounts of the obligations recorded therein; provided that the failure of any Lender or the Credit Facility Agent to maintain such Register or accounts or any error therein shall not in any manner affect the obligation of the Borrower to repay the Loans in accordance with the terms of this Agreement. In the event of any conflict between the accounts and records maintained by any Lender and the accounts and records of the Credit Facility Agent in respect of such matters, the accounts and records of the Credit Facility Agent shall control, in the absence of manifest error.

 

10


(g) In addition to such accounts or records described in clauses (d) and (e) of this Section 2.06 (Funding), the Loans made by each Lender may, upon the request of any Term Lender, be evidenced by a Term Loan Note or Term Loan Notes, in the case of Term Loans, or a Working Capital Loan Note or Working Capital Loan Notes, in the case of Working Capital Loans, in each case, duly executed on behalf of the Borrower and dated the date of any request therefor by a Lender. Each such Note shall have all blanks appropriately filled in, and shall be payable to such Lender and its registered assigns in a principal amount equal to the Term Loan(s) and Working Capital Loan(s) of such Lender; provided that each Lender may attach schedules to its respective Note(s) and endorse thereon the date, amount and maturity of its respective Loan(s).

Section 2.07 Termination or Reduction of Commitments. (a) (i) All unused Term Loan Commitments, if any, shall be automatically and permanently terminated (without premium or penalty) as of 5:00 p.m. on the last day of the Term Loan Availability Period that is a Business Day and (ii) all then-unused Working Capital Commitments, if any, shall be automatically and permanently terminated (without premium or penalty) as of 5:00 p.m. on the last day of the Working Capital Availability Period that is a Business Day.

(b) The Borrower may cancel or reduce permanently the whole or any part of the unutilized Term Loan Commitments and/or Working Capital Commitments (together with a corresponding ratable cancellation or reduction of the Issuing Bank Limits for each Issuing Bank by the amount by which the Issuing Bank Limits exceed the Aggregate Working Capital Commitments after giving effect to the cancellation or reduction of unutilized Working Capital Commitments), in either case, in accordance with Section 3.2 (Right of Repayment and Cancellation in Relation to a Single Facility Lender), Section 3.7 (Pro Rata Payment) and Section 3.8 (Reductions and Cancellations of Facility Commitments) of the Common Terms Agreement (provided that Section 3.8(c) thereof shall not apply to a reduction or cancellation of Working Capital Commitments) and upon at least three (3) Business Days’ prior written notice to the Credit Facility Agent (with a copy to any applicable Issuing Bank) and certification by the Borrower to the Credit Facility Agent that the letter of credit capacity under the portion of the Working Capital Commitments to be cancelled or reduced, after taking into account other funding sources irrevocably available to the Obligors, is not required to satisfy any express obligation of either Obligor to provide performance security; provided that, (x) the Borrower may not cancel or reduce any part of the Contingency Reserve Term Loan Commitments until the Project Completion Date and (y) in the event the Borrower cancels or reduces any part, but not all, of the Commitments prior to the Project Completion Date(other than in accordance with Section 6.3 (Replacement Senior Debt) of the Common Terms Agreement), the Borrower shall deliver to the Credit Facility Agent a certification (confirmed in writing by the Independent Engineer) that such cancellation or reduction will not result in the Obligors’ having an insufficient amount of committed or funded capital to fund (on the basis of all other available funds, including funds in the Construction Account and remaining Commitments) the remaining expenditures required to achieve the Project Completion Date by the Date Certain; provided, further, that, in accordance with Section 3.8 (Reductions and Cancellations of Facility

 

11


Commitments) and Section 3.7(b)(i) (Pro Rata Payments) of the Common Terms Agreement and Section 2.3(a) (Payments and Prepayments – Pro Rata Payment of Senior Debt Obligations) of the Common Security and Account Agreement (i) any such cancellation of Working Capital Commitments and Issuing Bank Limits may be made without pro rata cancellation of Facility Commitments under any other Facility Agreements then in effect and (ii) the Working Capital Lenders shall not be entitled to pro rata cancellation in the case of a cancellation of Facility Commitments under any other Facility Agreements. Where such cancellation or reduction is to be made pro rata, the applicable Commitments and Issuing Bank Limits (if such cancellation or reduction is with respect to Working Capital Commitments) shall be automatically and permanently reduced pro rata among all Lenders and Issuing Banks holding such Commitments and Issuing Bank Limits in accordance with their respective Commitment Percentages. Any such partial cancellation or reduction (A) of Term Loan Commitments pursuant to this Section 2.07(b) shall be in a minimum amount of $5,000,000 and (B) of Working Capital Commitments shall be in an amount of $5,000,000 or an integral multiple of $5,000,000 in excess thereof (or, in each case, if less the remaining amount of such Commitment). From the effective date of any such reduction or cancellation, the Commitment Fees shall be computed on the undrawn portion of the applicable Commitments as so reduced or cancelled.

(c) On the date of incurrence of any Replacement Senior Debt in accordance with Section 6.3 (Replacement Senior Debt) of the Common Terms Agreement incurred to replace all or any part of the Term Loan, the Term Loan Commitments of the Term Lenders shall be reduced in accordance with Section 3.8(a) (Reductions and Cancellations of Facility Commitments) of the Common Terms Agreement; provided that the Borrower shall be deemed to have repaid Term Loans and cancelled Facility Commitments on a pro rata basis by applying the proceeds of such Replacement Senior Debt first to repay any outstanding Term Loans in accordance with Section 4.16(c) (Pro Rata Treatment), and, to the extent any Replacement Senior Debt proceeds remain, secondly to cancel Term Loan Commitments that subsequently remain available to be drawn on a pro rata basis. On the date of incurrence of any Replacement Senior Debt in accordance with Section 6.3 (Replacement Senior Debt) of the Common Terms Agreement, no pro rata repayment of Working Capital Loans or cancellations of Working Capital Commitments shall be required to be made by the Obligors unless such Replacement Senior Debt has been incurred to replace all or any part of the Working Capital Loans and/or Working Capital Commitments.

(d) The Borrower shall have the right to replace any Non-Consenting Lender on a non-pro rata basis, pursuant to Section 5.04(b) (Obligation to Mitigate).

(e) All unused Commitments, if any, shall be terminated upon the occurrence and Continuance of a Loan Facility Event of Default if required pursuant to Section 9.02 (Acceleration Upon Bankruptcy) or Section 9.03 (Action Upon Event of Default) in accordance with the terms thereof.

Section 2.08 [Reserved].

Section 2.09 Incremental Commitments.

 

12


(a) The Borrower may from time to time, by written notice to the Credit Facility Agent (a “Working Capital Commitment Increase Notice”), request increases in the Working Capital Commitments (together with any applicable corresponding increases in the Issuing Bank Limits) of the relevant Working Capital Lender, Issuing Bank or by any other Person that is an Eligible Assignee or satisfies the rating requirement set forth in the definition of “Issuing Bank”, as applicable (each, a “Working Capital Commitment Increase”), up to an aggregate principal amount not to exceed the maximum amount of Working Capital Debt permitted pursuant to Section 6.2(a) (Working Capital Debt) of the Common Terms Agreement.

(b) The Working Capital Commitment Increase Notice shall specify (i) the date on which the Borrower proposes that such Working Capital Commitment Increase shall be effective, which shall be a date not less than thirty (30) days after the date on which such notice is delivered to the Credit Facility Agent, (ii) the amounts of the Working Capital Commitment Increase (including any proposed increase in Non-Fronting Limit or Fronting Limit of an Issuing Bank) and (iii) the identity of each Working Capital Lender, Issuing Bank or other Person that is an Eligible Assignee or satisfies the rating requirement set forth in the definition of “Issuing Bank”, as applicable (each, an “Incremental Lender/Issuing Bank”) to whom the Borrower proposes any portion of the Working Capital Commitment Increase be allocated and the amounts of such allocations; provided that, any Working Capital Lender, Issuing Bank or other Person approached to provide all or a portion of the Working Capital Commitment Increase may elect or decline, in its sole and absolute discretion, to participate.

(c) Each Working Capital Commitment Increase shall become Working Capital Commitments, Issuing Bank Limits, Non-Fronting Limits or Fronting Limits (as applicable) (or, in the case of an increase in the commitment of an existing Working Capital Lender or Issuing Bank, an increase in such Working Capital Lender’s or Issuing Bank’s applicable Working Capital Commitment, Issuing Bank Limit, Non-Fronting Limit or Fronting Limit (as applicable)) under this Agreement pursuant to an amendment (such amendment, an “Incremental Amendment”) to this Agreement executed by the Borrower, the Credit Facility Agent and each Incremental Lender/Issuing Bank (with the consent of no other Working Capital Lender being required) which provides solely for (i) the increase in the applicable Working Capital Commitments, Issuing Bank Limits, Non-Fronting Limits or Fronting Limits (as applicable) proposed in the applicable Working Capital Commitment Increase Notice and consented to by the applicable Incremental Lender/Issuing Bank, (ii) amendments required to reflect the relative unfunded Commitments of the Incremental Lenders/Issuing Banks and (iii) the joinder of each Incremental Lender/Issuing Bank that is not already an existing Working Capital Lender or Issuing Bank party to this Agreement. The effectiveness of any Incremental Amendment shall be subject solely to the conditions that (A) no Loan Facility Event of Default or Unmatured Loan Facility Event of Default shall exist on such date of effectiveness before or after giving effect to such Working Capital Commitment Increase, (B) each Incremental Lender that is not already a Working Capital Lender shall be entitled to receipt of any required reliance letters in respect of the legal opinions provided to the Credit Facility Agent pursuant to Section 4.1(f) (Conditions to Closing Date and Initial Advance – Opinions from Counsel) of the Common Terms Agreement, (C) since the time of the financial statements most recently provided pursuant to Section 10.1(a) (Accounting, Financial and Other Information) of the Common Terms Agreement no developments have occurred which, individually or in the aggregate have resulted in or could

 

13


reasonably be expected to result in a Material Adverse Effect, (D) each Incremental Lender/Issuing Bank who is not already a Working Capital Lender or Issuing Bank is reasonably acceptable to the Credit Facility Agent and each Issuing Bank and (E) the Intercreditor Agent has received, at least three (3) Business Days before the effectiveness of such Incremental Amendment, a certificate from the Borrower that (1) identifies each holder of Working Capital Commitments (after giving effect to the applicable Working Capital Commitment Increase) and (2) attaches a copy of the proposed Incremental Amendment.

Section 2.10 Use of Proceeds.

(a) The Borrower shall be permitted to use the proceeds of:

(i) Term Loans funded from the Base Term Loan Commitment solely: (A) to pay Project Costs, including the payment of Permitted Completion Costs and funding the Senior Facilities Debt Service Reserve Account and the Contingency Reserve Account, (B) to make Authorized Investments, (C) to reimburse Drawstop Equity Contributions previously made in accordance with Section 11.2(c) of the Common Terms Agreement (Certain Restricted Payments) and Section 4.5(c) (Deposits and Withdrawals – Construction Account) of the Common Security and Account Agreement, (D) to make the Initial Advance into the Credit Agreement Reserve Account pursuant to Section 4.5(h) (Deposits and Withdrawals – Credit Agreement Reserve Account) of the Common Security and Account Agreement and (E) to pay transaction costs, fees and expenses in connection with the closing of the Senior Debt and the Development; and

(ii) Term Loans funded from the Contingency Reserve Term Loan Commitment solely (A) prior to the Project Completion Date, to fund the Contingency Reserve Account for application to pay Project Costs, to the extent the aggregate amount of funds then on deposit in (x) the Pre-Completion Revenue Account (which funds have been transferred to the Contingency Reserve Account in accordance with Section 4.5(b)(ii)(C) of the Common Security and Account Agreement (Deposits and Withdrawals – Pre-Completion Revenues Account)) and (y) without duplication of the amounts described in the foregoing clause (x), the Contingency Reserve Account are insufficient to fund such Project Costs and (B) on the Project Completion Date, to fund the withdrawals and transfers contemplated by Section 14.2 (Project Completion Date Waterfall) of the Common Terms Agreement.

(b) The Borrower shall be permitted to use the Letters of Credit and the proceeds of Working Capital Loans solely for working capital purposes of the Obligors, including to satisfy the Obligors’ credit support obligations under the Material Project Agreements; provided, that prior to the Project Completion Date, the Borrower shall be permitted to use the proceeds of Working Capital Loans solely (i) for purchases of natural gas required by the Borrower for testing or operations of the Project Facilities and (ii) to the extent the Borrower has entered into one or more agreements, in each case with a third party who is not an Affiliate of the Borrower, for the purchase and sale of LNG that fully mitigates any commodity price risk resulting from the purchase of natural gas contemplated by the immediately foregoing clause (i) such that the Borrower has contracted to achieve a positive margin from the sale of LNG associated with such

 

14


purchased gas volumes, as certified by an Authorized Officer (who is a financial officer) of the Borrower; provided further, that the Borrower shall not borrow amounts under the Working Capital Facility or use the proceeds of Working Capital Loans to meet any requirement under any other Senior Debt Instrument governing the Working Capital Debt that the Borrower reduce the principal amount relating to any revolving loans under such other Senior Debt Instrument to $0 for a period of at least five (5) consecutive Business Days at least once per calendar year (it being acknowledged and agreed that the foregoing shall not limit the utilization by the Borrower of other Indebtedness that is permitted to be incurred pursuant to Section 12.14 (Limitation on Indebtedness) of the Common Terms Agreement for such purposes to the extent the terms and conditions of such Indebtedness permit such utilization).

ARTICLE III

LETTERS OF CREDIT

Section 3.01 Letters of Credit.

(a) Subject to the terms and conditions set forth herein and, as applicable, the terms and conditions set forth in the Common Terms Agreement, during the Working Capital Availability Period, the Borrower may (but is not required to), deliver to (1) the Credit Facility Agent (which shall promptly distribute copies thereof to the Working Capital Lenders), (2) the Issuing Bank designated by the Borrower (with the consent of such Issuing Bank in its sole discretion) with respect to Fronted Letters of Credit and (3) each Issuing Bank with a Non-Fronting Limit with respect to Non-Fronted Letters of Credit, a letter of credit request substantially in the form of Schedule B-3 to the Common Terms Agreement (Issuance Request Form (Letters of Credit) or such other form as requested by the Borrower and reasonably acceptable to the applicable Issuing Bank (a “Request for Issuance”) for the issuance, extension, modification or amendment of a Letter of Credit from time to time during the Working Capital Availability Period. Each Request for Issuance shall include (i) the date (which shall be a Business Day, but in no event later than the date that occurs five (5) Business Days prior to the Final Maturity Date) of issuance of such Letter of Credit (or the date of effectiveness of such extension, modification or amendment) and the stated expiry date thereof (which will be consistent with Section 3.01(d)), (ii) the proposed stated amount of such Letter of Credit, (iii) the intended beneficiary of such Letter of Credit, (iv) a description of the intended use of such Letter of Credit and (v) whether such Letter of Credit is to be a Fronted Letter of Credit or a Non-Fronted Letter of Credit. Each Request for Issuance shall be irrevocable unless modified or rescinded by the Borrower not less than three (3) Business Days prior to the proposed date of issuance (or effectiveness) specified therein.

(b) The Borrower may request Letters of Credit up to the lesser of (i) an aggregate stated amount for all requested and issued Letters of Credit of the aggregate of the Issuing Bank Limits of all Issuing Banks and (ii) the Aggregate Working Capital Commitments; provided, in each case, that no Issuing Bank shall be required to issue any Letter of Credit or any amendment to increase the face or stated amount of any Letter of Credit if, after such issuance or amendment, (A) the aggregate Working Capital Commitment Exposure for all Working Capital Lenders shall exceed the Aggregate Working Capital Commitments, (B) the LC Exposure of such Issuing Bank with a Fronting Limit shall exceed its Fronting Limit, (C) the LC Exposure of such Issuing

 

15


Bank with a Non-Fronting Limit shall exceed its Non-Fronting Limit, (D) the LC Exposure of such Issuing Bank shall exceed its Issuing Bank Limit or (D) the Working Capital Commitment Exposure of such Issuing Bank shall exceed its Working Capital Commitment in its capacity as a Working Capital Lender. For the avoidance of doubt, subject to compliance with the foregoing requirements and Sections 3.01(a) and 3.01(f), the Borrower may request Fronted Letters of Credit from an Issuing Bank with a Fronting Limit up to the Issuing Bank’s full Fronting Limit.

(c) Promptly after its receipt of a Request for Issuance, the Issuing Bank will confirm with the Credit Facility Agent (in writing) that the Credit Facility Agent has received a copy of such Request for Issuance from the Borrower and, if not, the Issuing Bank will provide the Credit Facility Agent with a copy thereof. Unless the Issuing Bank has received notice (in writing) from the Credit Facility Agent (including at the request of any Working Capital Lender) no later than three (3) Business Days prior to the proposed date of issuance (or effectiveness) (i) directing the Issuing Bank not to issue (or extend, amend or modify) such Letter of Credit as a result of the limitations set forth in Section 3.01(b), or (ii) that one or more of the applicable conditions precedent in Section 7.03 (Conditions to Each Working Capital Advance) is not then satisfied or waived, then (A) the applicable Issuing Bank shall issue (or extend, modify or amend) each Letter of Credit not later than 1:00 p.m. on the later of (1) the proposed date of issuance (or effectiveness) specified in such Request for Issuance and (2) three (3) Business Days after the receipt of the Request for Issuance (taking into account that any Request for Issuance received after 1:00 p.m. on any Business Day will be deemed received on the next Business Day), and (B) such issuance (or effectiveness) shall be subject to the terms and conditions hereof, including fulfillment of the applicable conditions precedent and the other requirements set forth herein (including Sections 3.01(a) and 3.01(f)). An Issuing Bank that issues (or extends, amends or modifies) a requested Letter of Credit pursuant to this Section 3.01 shall issue (or extend, amend or modify) such Letter of Credit to the Borrower or directly to the intended beneficiary and shall provide notice and a copy thereof to the Intercreditor Agent and the Credit Facility Agent, which, in the case of a Fronted Letter of Credit, shall promptly furnish copies thereof to the Working Capital Lenders, and to the extent that such Letter of Credit was issued directly to the intended beneficiary, such Issuing Bank shall provide notice and a copy thereof to the Borrower.

(d) Each Letter of Credit shall expire no later than the earlier of (i) one year from the date of issuance of such Letter of Credit and (ii) five (5) Business Days prior to the Working Capital Loan Termination Date. Each Letter of Credit may, if requested by the Borrower, provide that it will be automatically renewed or extended for a stated period of time at the end of its then-scheduled expiration date and each successive expiration date (but in any event shall not be extended for longer than one year from the date of effectiveness of each such extension or beyond five (5) Business Days prior to the Working Capital Loan Termination Date) unless the Issuing Bank that issued the Letter of Credit notifies the beneficiary thereof no later than thirty (30) days prior to such expiration date that such Issuing Bank elects not to renew or extend such Letter of Credit. In no event shall the Working Capital Lenders have any obligation to pay any amount to (or for the account of) any Issuing Bank or any other Person, in respect of a drawing under a Letter of Credit that occurs after the Final Maturity Date.

 

16


(e) Notwithstanding anything in this Agreement to the contrary, no Issuing Bank will have any obligation to issue or renew, or extend the expiry date of, any Letter of Credit if (i) any judgment, order, or decree of any Governmental Authority or arbitrator shall by its terms purport to enjoin or restrain such Issuing Bank from issuing or renewing or extending the expiry date of such Letter of Credit or (ii) any Government Rule or any directive (whether or not having the force of law) from any Governmental Authority with jurisdiction over such Issuing Bank shall prohibit, or direct that such Issuing Bank refrain from, the issuance of new letters of credit or the renewal or extension of the expiry date of issued letters of credit generally or the issuance, renewal or extension of the expiry date of a Letter of Credit specifically or shall impose upon such Issuing Bank with respect to such Letter of Credit any restriction, reserve, or capital requirement, or shall impose upon such Issuing Bank any loss, cost, or expense. Each Issuing Bank shall provide the Borrower with prompt notice of the occurrence of any event described in this Section 3.01(e) not later than two (2) Business Days after obtaining knowledge of the occurrence of any such event.

(f) The Borrower may request that a Letter of Credit be Fronted Letter of Credit or a Non-Fronted Letter of Credit; provided that, (i) the Borrower may only request Fronted Letters of Credit from an Issuing Bank that is specified in this Agreement as having a Fronting Limit and who has consented to issue such Fronted Letter(s) of Credit in accordance with Section 3.01(a), and (ii) if the Borrower wishes to request Non-Fronted Letters of Credit, the Borrower shall determine the specific aggregate amount to be covered by such Letters of Credit to be provided to a specific beneficiary (the “Non-Fronted LC Amount”), and it shall make requests for Non-Fronted Letters of Credit simultaneously to all the Issuing Banks under this Agreement such that the aggregate stated amount of all such Non-Fronted Letters of Credit issued to such beneficiary is equal to the Non-Fronted LC Amount and the stated amount of the Non-Fronted Letter of Credit of each individual Issuing Bank is equal to its Commitment Percentage of the Non-Fronted LC Amount. No Working Capital Lender is required to participate in the extension of credit resulting from the issuance (or extension, modification or amendment) of a Non-Fronted Letter of Credit issued by an Issuing Bank other than itself. Each Working Capital Lender severally agrees with each Issuing Bank to participate in an amount equal to its Commitment Percentage in the extension of credit resulting from the issuance (or extension, modification or amendment) of a Fronted Letter of Credit by such Issuing Bank and each drawing of the LC Available Amounts thereunder, in the manner and the amount provided in Section 3.02 (Reimbursement to Issuing Banks), and the issuance of such Fronted Letter of Credit shall be deemed to be a confirmation by the Issuing Bank and each Working Capital Lender of such participation in such amount; provided that, no Working Capital Lender shall be required to participate in a Fronted Letter of Credit to the extent such Working Capital Lender’s Working Capital Commitment Exposure would exceed its Working Capital Commitment as a result of such participation.

 

17


(g) In addition to the date of issuance, stated expiry date, stated amount, beneficiary, intended use and request for a Fronted Letter of Credit or Non-Fronted Letter of Credit specified in the applicable Request for Issuance, each Letter of Credit shall provide (unless the Borrower specifies otherwise in such Request for Issuance) for:

(i) payment in immediately available funds in US Dollars on a Business Day;

(ii) multiple drawings and partial drawings;

(iii) applicability of the International Standby Practices 1998, International Chamber of Commerce Publication No. 590 (1998) (“ISP98”), Uniform Customs and Practice for Documentary Credits, International Chamber of Commerce Publication No. 600 (2007) (“UCP 600”), or such other rules as the Borrower and the applicable Issuing Bank shall agree, and shall, as to matters not governed by ISP98, UCP 600 or such other rules, be governed and construed in accordance with the laws of the State of New York and applicable U.S. federal law;

(iv) a drawing by the beneficiary of the full available amount thereof if either (A) the Issuing Bank that issued the Letter of Credit ceases to satisfy the minimum credit ratings for an Issuing Bank hereunder (as set forth in the definition of “Issuing Bank” in Exhibit A (Definitions)) and such Letter of Credit has not been replaced by an Issuing Bank satisfying such minimum credit ratings within thirty (30) days or such shorter number of days as required under the document, if any, with respect to which such Letter of Credit is issued; provided that, the right to draw under this clause (A) shall only be included in the applicable Letter of Credit to the extent required under such document with respect to which such Letter of Credit is issued or (B) the Issuing Bank that issued the Letter of Credit notifies the Borrower (which shall promptly notify the beneficiary) no later than 60 days prior to the then-scheduled expiration date that such Issuing Bank elects not to renew or extend such Letter of Credit; and

(v) in the case of a Non-Fronted Letter of Credit, the beneficiary will be required to certify that it is making a pro rata draw with all other Letters of Credit issued in favor of such beneficiary in respect of a Non-Fronted LC Amount based on the percentage of such Non-Fronted Letter of Credit to Non-Fronted LC Amount as notified to the beneficiary by the Borrower.

Section 3.02 Reimbursement to Issuing Banks.

(a) An Issuing Bank shall give the Credit Facility Agent, the Collateral Agent, the Borrower and each of the Working Capital Lenders prompt notice of any payment made by such Issuing Bank in accordance with the terms of any Letter of Credit issued by such Issuing Bank (an “LC Payment Notice”) no later than 10:00 a.m. on the Business Day immediately succeeding the date of such payment by such Issuing Bank.

(b) Upon delivery to the Borrower of an LC Payment Notice on or before 10:00 a.m., New York City time, on the Business Day immediately succeeding the date of such payment by an Issuing Bank, the Borrower shall either (i) on or before 12:00 noon on such Business Day, reimburse such Issuing Bank for such payment (an “LC Reimbursement Payment”) by paying to the Credit Facility Agent, for the account of such Issuing Bank, an amount equal to the payment made by such Issuing Bank plus interest on such amount at a rate per annum equal to the Base Rate plus the Applicable Margin for Base Rate Loans (provided that, if an Issuing Bank delivers

 

18


an LC Payment Notice to the Borrower after 10:00 a.m. New York City time on the Business Day immediately succeeding the date of payment by such Issuing Bank, the Borrower shall make the LC Reimbursement Payment on or before 12:00 noon New York City time on the next succeeding Business Day) or (ii) (x) provide written notice to such Issuing Bank and the Credit Facility Agent electing to have the reimbursement obligation converted into an LC Loan in accordance with Sections 3.02(c) and (f) or (y) not make the LC Reimbursement Payment as required under Section 3.02(b)(i) (Reimbursement to Issuing Banks), in which case, in the case of this clause (ii), such reimbursement obligation shall automatically convert to an LC Loan as of such time; provided, that no Loan Facility Event of Default shall have occurred and been Continuing as of the time of the applicable payment made under the Letter of Credit. An Issuing Bank’s failure to provide an LC Payment Notice shall not relieve the Borrower of its obligation to reimburse such Issuing Bank for any payment it makes under any Letter of Credit. In the case of any Non-Fronted Letters of Credit issued with respect to a specific Non-Fronted LC Amount, the Borrower may not elect to make an LC Reimbursement Payment and/or convert a reimbursement obligation into a LC Loan for some but not all the Issuing Banks providing Non-Fronted Letters of Credit with respect to such Non-Fronted LC Amount.

(c) If the Borrower fails to make the LC Reimbursement Payment as required under Section 3.02(b) (Reimbursement to Issuing Banks) or provides written notice to such Issuing Bank and the Credit Facility Agent electing to have the reimbursement obligation converted into an LC Loan, such reimbursement obligation shall automatically convert to an LC Loan; provided, that no Loan Facility Event of Default shall have occurred and been Continuing as of the time of the applicable payment made under the Letter of Credit. If such LC Loan relates to a Fronted Letter of Credit, the Credit Facility Agent shall promptly notify each of the Working Capital Lenders of the amount of its share of the payment made under such Fronted Letter of Credit, which shall be such Working Capital Lender’s Commitment Percentage of such amount paid by such Issuing Bank (the “Working Capital Lender Payment Notice”). Subject to Section 3.01(f) (Letters of Credit), each Working Capital Lender hereby severally agrees to pay the amount specified in the Working Capital Lender Payment Notice in immediately available funds to the Credit Facility Agent for the account of such Issuing Bank with respect to a Fronted Letter of Credit plus interest on such amount at a rate per annum equal to the Federal Funds Effective Rate from the date of such payment by such Issuing Bank to the date of payment to such Issuing Bank by such Working Capital Lender. Each Working Capital Lender shall make such payment by not later than 4:00 p.m. New York City time on the date it received the Working Capital Lender Payment Notice (if such notice is received at or prior to 1:00 p.m. New York City time) and before 12:00 noon New York City time on the next succeeding Business Day following such receipt (if such notice is received after 1:00 p.m. New York City time). In the case of Fronted Letters of Credit, each Working Capital Lender shall severally indemnify and hold harmless such Issuing Bank from and against any and all losses, liabilities (including liabilities for penalties), actions, suits, judgments, demands, costs, and expenses (including reasonable attorneys’ fees and expenses) resulting from any failure on the part of such Working Capital Lender to provide, or from any delay in providing, the Credit Facility Agent for the account of such Issuing Bank with its Commitment Percentage of the amount paid under the Fronted Letter of Credit but no such Working Capital Lender shall be so liable for any such failure on the part of or caused by any other Working Capital Lender or the willful misconduct or gross negligence, as determined by a court of competent jurisdiction by a final and non-appealable order, of the Credit Facility Agent.

 

19


Each Working Capital Lender’s obligation to make each such payment to the Credit Facility Agent for the account of the applicable Issuing Bank in the case of payments made in respect of a Fronted Letter of Credit shall be several and not joint and shall not be affected by (A) the occurrence or continuance of any Loan Facility Event of Default (except as set forth in Section 3.02(b) and this Section 3.02(c)), (B) the failure of any other Working Capital Lender to make any payment under this Section 3.02 (Reimbursement to Issuing Banks), or (C) the date of the drawing under the applicable Letter of Credit issued by the applicable Issuing Bank; provided that, such drawing occurs prior to the earlier of (i) the Final Maturity Date or (ii) the termination date of the applicable Fronted Letter of Credit. Each Working Capital Lender further agrees that each such payment shall be made without any offset, abatement, withholding or reduction whatsoever.

(d) The Credit Facility Agent shall pay to the applicable Issuing Bank in immediately available funds the amounts paid in respect of a Fronted Letter of Credit pursuant to Section 3.02(b) (Reimbursement to Issuing Banks) and Section 3.02(c) (Reimbursement to Issuing Banks) before the close of business on the day such payment is received; provided that, any amount received by the Credit Facility Agent that is due and owing to such Issuing Bank and remains unpaid to such Issuing Bank on the date of receipt shall be paid on the next succeeding Business Day with interest payable at the Federal Funds Effective Rate.

(e) For so long as any Working Capital Lender is a Defaulting Lender under clause (a) of the definition thereof, such Defaulting Lender’s participation in LC Exposure shall be reallocated in accordance with Section 4.18(b) (Defaulting Lenders).

(f) Each payment made by a Working Capital Lender under subsection (c) above shall constitute an LC Loan deemed made by such Working Capital Lender to the Borrower on the date of such payment by an Issuing Bank under a Fronted Letter of Credit issued by such Issuing Bank. All such payments by the Working Capital Lenders in respect of any one such payment by such Issuing Bank shall constitute a single LC Loan hereunder. Each payment made by an Issuing Bank in respect of a Non-Fronted Letter of Credit that is not reimbursed by the Borrower or that is converted into an LC Loan by notice from the Borrower pursuant to clause (c) above shall constitute an LC Loan deemed made by such Issuing Bank in its capacity as a Working Capital Lender. LC Loans that are converted to LIBORSOFR Loans in respect of Non-Fronted Letters of Credit with respect to a specific Non-Fronted LC Amount shall constitute a single LIBORSOFR Loan for the purposes of Section 4.05(e) (Interest Rates) hereunder. Each LC Loan initially shall be a Base Rate Loan.

Section 3.03 Obligations Absolute. The payment obligations of each Working Capital Lender under Section 3.02(c) (Reimbursement to Issuing Banks) and of the Borrower under this Agreement in respect of any payment under any Letter of Credit and any LC Loan shall be unconditional and irrevocable (subject only to the Borrower’s and each Working Capital Lender’s right to bring suit against an Issuing Bank pursuant to Section 3.04 (Liability of the Issuing Banks and the Working Capital Lenders) following the reimbursement of such Issuing Bank for any such payment), and shall be paid strictly in accordance with the terms of this Agreement under all circumstances, including the following circumstances:

(a) any lack of validity or enforceability of any Finance Document or any other agreement or instrument relating thereto or to such Letter of Credit;

 

20


(b) any amendment or waiver of, or any consent to departure from, all or any of the Finance Documents;

(c) the existence of any claim, set-off, defense or other right which the Borrower may have at any time against any beneficiary, or any transferee, of such Letter of Credit (or any Persons for whom any such beneficiary or any such transferee may be acting), any Issuing Bank, or any other Person, whether in connection with this Agreement, the transactions contemplated herein or by such Letter of Credit, or any unrelated transaction;

(d) any statement or any other document presented under such Letter of Credit proving to be forged, fraudulent, invalid or insufficient in any respect or any statement therein being untrue or inaccurate in any respect;

(e) payment in good faith by an Issuing Bank under any Letter of Credit issued by such Issuing Bank against presentation of a draft or certificate which does not comply with the terms of such Letter of Credit; or

(f) any other circumstance or happening whatsoever, whether or not similar to any of the foregoing.

Section 3.04 Liability of the Issuing Banks and the Working Capital Lenders. The Borrower assumes all risks of the acts and omissions of any beneficiary or transferee of any Letter of Credit, and none of the Credit Facility Agent, the Issuing Banks, the Working Capital Lenders nor any of their respective Related Parties shall be liable or responsible for (a) the use that may be made of such Letter of Credit or any acts or omissions of any beneficiary or transferee thereof in connection therewith; (b) the validity, sufficiency or genuineness of documents, or of any endorsement thereon, even if such documents should prove to be in any or all respects invalid, insufficient, fraudulent or forged; (c) payment by the applicable Issuing Bank against presentation of documents that do not comply with the terms of such Letter of Credit, including failure of any documents to bear any reference or adequate reference to such Letter of Credit; or (d) any other circumstances whatsoever in making or failing to make payment under such Letter of Credit; provided that, in each case, payment by the applicable Issuing Bank shall not have constituted gross negligence or willful misconduct as determined by a court of competent jurisdiction by a final and non-appealable order, in which event the Borrower and each Working Capital Lender shall have the right to bring suit against an Issuing Bank, and such Issuing Bank shall be liable to the Borrower and any Working Capital Lender, to the extent of any direct, as opposed to consequential, damages suffered by the Borrower or such Working Capital Lender caused by such Issuing Bank’s willful misconduct or gross negligence as determined by a court of competent jurisdiction by a final and non-appealable order, including such Issuing Bank’s willful failure to make timely payment under such Letter of Credit following the presentation to it by the beneficiary thereof of a draft and accompanying certificate(s) which strictly comply with the terms and conditions of such Letter of Credit.

 

21


Section 3.05 Resignation as an Issuing Bank. Any Issuing Bank may, upon no less than thirty (30) days’ prior written notice to the Borrower (with a copy to the Credit Facility Agent, to be distributed to each Working Capital Lender) resign as an Issuing Bank, effective upon the appointment of a successor Issuing Bank in accordance with this Section 3.05. In the event of any such resignation as an Issuing Bank, the Borrower shall be entitled to appoint a successor Issuing Bank hereunder from among the Working Capital Lenders (provided, that the Borrower may not so appoint any Working Capital Lender if, as a result of such appointment, such Working Capital Lender’s (i) Working Capital Commitment Exposure would exceed its Working Capital Commitment or (ii) LC Exposure would exceed its Issuing Bank Limit, Fronting Limit or Non-Fronting Limit, as applicable) who meet the requirements hereunder to be an Issuing Bank; provided, however, that no failure by the Borrower to appoint any such successor shall affect the resignation of any Issuing Bank. If any Working Capital Lender resigns as an Issuing Bank, it shall retain all the rights, powers, privileges and duties of Issuing Bank hereunder with respect to all Letters of Credit that it issued, including Letters of Credit outstanding as of the effective date of its resignation as an Issuing Bank and all LC Exposure with respect thereto (including the right to require the Working Capital Lenders to make LC Loans or fund participations in Letters of Credit). Upon the appointment of a successor Issuing Bank and such successor Issuing Bank’s acceptance, in writing, of the appointment and agreement to be bound by all of the terms and conditions contained in this Agreement and the other Finance Documents binding on it in such capacity, (a) such successor shall succeed to and become vested with all of the rights, powers, privileges and duties of the Issuing Bank as the case may be and the successor Issuing Bank shall issue letters of credit in substitution for the Letters of Credit, if any, outstanding at the time of such succession or make other arrangements satisfactory to the applicable resigning Issuing Bank to effectively assume the obligations of such Issuing Bank with respect to such Letters of Credit.

Section 3.06 Non-Fronted Letters of Credit. The Borrower agrees that in the event that it has provided any Non-Fronted Letter of Credit in respect a Non-Fronted LC Amount, it shall instruct the beneficiary thereof to draw on such Non-Fronted Letter of Credit pro rata among all Non-Fronted Letters of Credit issued in respect of such Non-Fronted LC Amount. In the event that the Borrower has funded the Senior Debt Service Reserve Account using Non-Fronted Letters of Credit from each Issuing Bank, the Collateral Agent hereby agrees (without the need for any further action or instruction from any Senior Creditors) to draw on such Non-Fronted Letters of Credit only on a pro rata basis as notified by the Borrower to the Collateral Agent or, failing such notification, as provided to the Collateral Agent by the Credit Facility Agent on request.

Section 3.07 Reinstatement of Letters of Credit. The stated amount of each Letter of Credit shall be reduced by the amount of any payment made by the applicable Issuing Bank on a drawing thereunder. Once so reduced, the stated amount of such Letter of Credit may only be reinstated upon and to the extent of any reimbursement by the Borrower of such drawing or, if reimbursement of such drawing is made through LC Loans, upon and to the extent of payment by the Borrower of the LC Loans corresponding to such drawing, in each case, pursuant to Section 3.02 (Reimbursement to Issuing Banks). At least one (1) Business Day prior to the date of any such reinstatement of a Letter of Credit, the Borrower shall deliver to such Issuing Bank and the Credit Facility Agent a written request for reinstatement signed by an Authorized Officer of the Borrower and in form and substance satisfactory to such Issuing Bank. Upon the effectiveness of any such reinstatement, such Issuing Bank shall notify the Borrower, the Credit Facility Agent and the beneficiary of the reinstated Letter of Credit and shall indicate in such notice the new stated amount of such Letter of Credit.

 

22


ARTICLE IV

REPAYMENTS, PREPAYMENTS, INTEREST AND FEES

Section 4.01 Repayment of Term Loan Advances.

(a) The Borrower unconditionally and irrevocably promises to pay to the Credit Facility Agent for the ratable account of each Term Lender the aggregate outstanding principal amount of the Term Loans on each CTA Payment Date beginning on the First Repayment Date, in accordance with the Amortization Schedule. In addition, following the making of any prepayments pursuant to this Agreement or Section 3.1 (CTA Payment Dates) of the Common Terms Agreement, including in connection with the incurrence of Replacement Senior Debt, the Credit Facility Agent shall, of its own motion or as reasonably requested by the Borrower, generate and promptly provide to the Intercreditor Agent and the Borrower a revised Amortization Schedule (in respect of which it shall have consulted with the Borrower). In any of the instances described above, the revised Amortization Schedule shall be delivered prior to the next Quarterly Payment Date and prepared in a manner that is consistent with the principles used to prepare the original Amortization Schedule. Any failure by the Credit Facility Agent to provide a revised Amortization Schedule as required pursuant to this Section 4.01 (Repayment of Term Loan Advances) shall not affect the Borrower’s obligations to pay the Term Loans in accordance with this Agreement.

(b) The repayment of principal by the Borrower for the Term Loans shall commence on the earlier of (such earlier date, the “First Repayment Date”):

(i) the first Quarterly Payment Date (or, if such date is not a Business Day, the Business Day immediately prior to such Quarterly Payment Date) occurring more than three calendar months following the Project Completion Date; and

(ii) March 31, 2023.

(c) Notwithstanding anything to the contrary set forth in Section 4.01(a) above, the final principal repayment installment on the Final Maturity Date shall in any event be in an amount equal to the aggregate principal amount of all Term Loans outstanding on such date.

Section 4.02 Repayment of LC Loans. The Borrower unconditionally and irrevocably promises to pay to the Credit Facility Agent for the ratable account of each Working Capital Lender the aggregate outstanding principal amount of each LC Loan no later than 5:00 p.m. on the Working Capital Loan Termination Date.

 

23


Section 4.03 Repayment of Working Capital Advances.

(a) The Borrower shall reduce the aggregate outstanding principal amount of all Working Capital Loans to zero Dollars ($0) for a period of five (5) consecutive Business Days at least once every calendar year; provided that, the Borrower will determine in its sole discretion when during any calendar year it elects to satisfy such requirement and the Credit Facility Agent shall have no duty to monitor compliance with this Section 4.03(a); provided further that the Borrower may not borrow amounts under any other Facility Agreement for Working Capital Debt in order to meet the requirement specified in this Section 4.03(a).

(b) Notwithstanding anything to the contrary set forth in Section 4.03(a), the Borrower unconditionally and irrevocably promises to pay to the Credit Facility Agent for the ratable account of each Working Capital Lender, on the Working Capital Loan Termination Date, an amount equal to the aggregate principal amount of all Working Capital Loans then-outstanding.

Section 4.04 Interest Payment Dates. (a) Interest accrued on each Loan shall be payable, without duplication, on the following dates (each, an “Interest Payment Date”):

(i) with respect to any repayment or prepayment of principal on such Loan, on the date of each such repayment or prepayment;

(ii) on the Final Maturity Date;

(iii) with respect to Working Capital Loans and LC Loans, the Working Capital Loan Termination Date;

(iv) with respect to LIBORSOFR Loans, (A) on the last day of each applicable Interest Period; provided, that in the case of any Interest Period that has a duration of more than three months, the Interest Payment Date in respect of such LIBORSOFR Loans shall also include each day that is three months (or an integral multiple thereof) after the first day of such Interest Period, and (B) if applicable, on any date on which such LIBORSOFR Loan is converted to a Base Rate Loan; and

(v) with respect to Base Rate Loans, on the last Business Day of each calendar quarter or, if applicable, any date on which such Base Rate Loan is converted to a LIBORSOFR Loan.

(b) Interest accrued on the Loans or other monetary Loan Obligations after the date such amount is due and payable (whether on the Final Maturity Date or any CTA Payment Date upon acceleration or otherwise) shall be payable upon demand.

(c) Interest hereunder shall be due and payable in accordance with the terms hereof before and after judgment, and before and after the occurrence of an event set forth in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement and (to the extent Section 9.01 (Events of Default) covers the events described in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement) Section 9.01 (Events of Default) of this Agreement.

 

24


Section 4.05 Interest Rates.

(a) Each LIBORSOFR Loan shall accrue interest at a rate per annum during each Interest Period applicable thereto equal to the sum of the LIBORAdjusted Term SOFR for such Interest Period plus the Applicable Margin for such Loan.

(b) On or before 1:00 p.m. at least three (3) U.S. Government Securities Business Days prior to the end of each Interest Period for each LIBORSOFR Loan, the Borrower shall deliver to the Credit Facility Agent an Interest Period Notice setting forth the Borrower’s election with respect to the duration of the next Interest Period applicable to such LIBORSOFR Loan, which Interest Period shall be one (1), two (2), three (3), or six (6) months in length (or, if available to all applicable Lenders, nine (9) or twelve (12)) months in lengthsuch other periods as may be agreed by the Credit Facility Agent and each Lender (including with respect to the Applicable Margin agreed to by all the Lenders with respect to any such Interest Period)); provided, that, (i) if any Loan Facility Declared Default has occurred and is Continuing, all LIBORSOFR Loans shall convert into Base Rate Loans and (ii) if any Unmatured Loan Facility Event of Default has occurred and is Continuing at the end of the then-current Interest Periods, all LIBORSOFR Loans shall convert into LIBORSOFR Loans with an Interest Period of one (1) month, in each case, at the end of the then-current Interest Periods (in which case the Credit Facility Agent shall so notify the Borrower and the Term Lenders). After such Loan Facility Declared Default or Unmatured Loan Facility Event of Default has ceased, the Borrower may convert each such Base Rate Loan or LIBORSOFR Loan with an Interest Period of one (1) month into a LIBORSOFR Loan in accordance with this Agreement by delivering an Interest Period Notice in accordance with Section 4.06 (Conversion Options).

(c) If the Borrower fails to deliver an Interest Period Notice in accordance with Section 4.05(b) (Interest Rates) above with respect to any LIBORSOFR Loan, such LIBORSOFR Loan shall be made as, or converted into, a Base Rate Loan at the end of the then-current Interest Period.

(d) Each LIBORSOFR Loan shall bear interest from (and including) the first day of the applicable Interest Period to (but excluding) the last day of such Interest Period (or the date such Loan is converted to a Base Rate Loan) at the interest rate determined as applicable to such LIBORSOFR Loan.

(e) Notwithstanding anything to the contrary contained herein, the Borrower shall have, in the aggregate, no more than ten (10) separate LIBORSOFR Loans outstanding at any one time.

(f) Each Base Rate Loan shall accrue interest at a rate per annum equal to the sum of the Base Rate plus the Applicable Margin for such Loan.

(g) All Base Rate Loans shall bear interest from and including the date such Loan is made (or the day on which LIBORSOFR Loans are converted to Base Rate Loans in accordance with Section 4.05(c) (Interest Rates) or 4.06 (Conversion Options) or under Article V (LIBOR AndSOFR and Tax Provisions)) to (but excluding) the date such Loan or portion thereof is paid at the interest rate determined as applicable to such Base Rate Loan (or the date such Loan is converted to a LIBORSOFR Loan).

 

25


(h) In connection with the use or administration of Term SOFR, the Credit Facility Agent, with the written consent of the Borrower (such consent not to be unreasonably withheld, conditioned or delayed), will have the right to make Conforming Changes from time to time and, notwithstanding anything to the contrary herein or in any other Finance Document, any amendments implementing such Conforming Changes will become effective without any further action or consent of any other party to this Agreement or any other Finance Document. The Credit Facility Agent will promptly notify the Borrower and the Lenders of the effectiveness of any Conforming Changes in connection with the use or administration of Term SOFR.

Section 4.06 Conversion Options. The Borrower may elect from time to time to convert LIBORSOFR Loans to Base Rate Loans or Base Rate Loans to LIBORSOFR Loans (subject to Sections 4.05(e) (Interest Rates), 5.01 (LIBOR Lending UnlawfulIllegality) and 5.02 (Inability to Determine LIBORApplicable Interest Rate)), as the case may be, by delivering a completed Interest Period Notice to the Credit Facility Agent notifying the Credit Facility Agent of such election no later than 12:00 noon on the third (3rd) Business Day preceding the proposed conversion date (which notice, in the case of conversions to LIBORSOFR Loans, shall specify the length of the initial Interest Period therefor); provided that, (i) no Base Rate Loan may be converted into a LIBORSOFR Loan when any Loan Facility Declared Default has occurred and is Continuing, and (ii) no Base Rate Loan may be converted into a LIBORSOFR Loan with an Interest Period greater than one month when any Unmatured Loan Facility Event of Default has occurred and is Continuing and, in each case, the Credit Facility Agent has determined not to permit such conversions. Upon receipt of any such notice, the Credit Facility Agent shall promptly notify each relevant Lender thereof.

Section 4.07 Post-Maturity Interest Rates; Default Interest Rates. If all or a portion of the principal amount of any Loan is not paid when due (whether on the Final Maturity Date, by acceleration or otherwise, or in the case of LC Loans, the Working Capital Loan Termination Date or otherwise) or any Loan Obligation (other than principal on the Loans) is not paid or deposited when due (whether on the Final Maturity Date, by acceleration or otherwise), (i) all such overdue amounts of principal on the Loans shall bear interest at a rate per annum equal to the rate that would otherwise be applicable thereto plus the Default Rate and (ii) all such other defaulted amounts of Loan Obligations (other than principal on the Loans) shall bear interest at a rate per annum equal to the rate then applicable to Base Rate Loans plus the Default Rate, from the date of such non-payment until the amount then due is paid in full (after as well as before judgment).

Section 4.08 Interest Rate Determination. The Credit Facility Agent shall determine the interest rate applicable to the Loans and shall give prompt notice of such determination to the Borrower and the applicable Lenders. In each such case, the Credit Facility Agent’s determination of the applicable interest rate shall be conclusive, in the absence of manifest error.

 

26


Section 4.09 Computation of Interest and Fees.

(a) All computations of interest for Base Rate Loans when the Base Rate is determined by the Credit Facility Agent’s “prime rate” shall be made on the basis of a year of 365 or 366 days, as the case may be, and actual days elapsed. All computations of interest for LIBORSOFR Loans, and for Base Rate Loans when the Base Rate is determined by LIBORAdjusted Term SOFR shall be made on the basis of a 360 day year and actual days elapsed. All computations of commissions or fees owed hereunder (other than Commitment Fees, Fronting Fees and LC Fees, which shall be computed in accordance with the provisions of Section 4.15 (Fees) below) shall be made on the basis of a year of 365 or 366 days, as the case may be, and actual days elapsed (including the first day but excluding the last day).

(b) Interest shall accrue on each Loan for the day on which the Loan is made, and shall not accrue on a Loan, or any portion thereof, for the day on which the Loan or such portion is paid; provided, that, any Loan that is repaid on the same day on which it is made shall bear interest for one day.

(c) Each computation by the Credit Facility Agent of interest or fees hereunder shall be conclusive and binding for all purposes, absent manifest error.

Section 4.10 Terms of All Prepayments. The Borrower shall make prepayments of Loans and all reductions and cancellations of Commitments in accordance with the terms of Article 3 (Repayment, Prepayment and Cancellation) of the Common Terms Agreement and subject to the following terms and the terms of Section 4.11 (Voluntary Prepayments) and Section 4.12 (Mandatory Prepayment):

(a) upon the prepayment of any Loans (whether a voluntary prepayment, a mandatory prepayment or a prepayment upon acceleration or otherwise), the Borrower shall satisfy all applicable provisions under this Agreement; and

(b) together with any prepayment of Loans, the Borrower shall pay to the Credit Facility Agent, for the account of the applicable Lenders which made any Loan being prepaid, the sum of the following amounts:

(i) the principal of, and accrued but unpaid interest on, the Loans to be prepaid;

(ii) any additional amounts required to be paid under Section 5.05 (Funding Losses), which payment shall be made within the time period after the applicable prepayment as is permitted under the Common Terms Agreement; and

(iii) any other Loan Obligations required to be paid to the respective Lenders in connection with any prepayment under the Finance Documents.

 

27


Section 4.11 Voluntary Prepayment.

(a) The Borrower may, in accordance with Section 3.5 (Voluntary Prepayments) of the Common Terms Agreement and on not less than three (3) Business Days’ prior written notice to the Credit Facility Agent, prepay in whole or in part amounts outstanding under the Credit Facility Agreement, without penalty or premium (other than any Breakage Costs incurred as set forth in Section 5.05 (Funding Losses)); provided, that, each voluntary prepayment of Loans shall be in incremental multiples of $1,000,000. Such notice may be conditional and subject to revocation as set forth in Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement. If any such notice is revoked in accordance with Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement, the Borrower shall pay any Breakage Costs incurred by any Lender as a result of such notice and revocation, as set forth in Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement. Prepayments of Working Capital Loans shall not result in any reduction in Working Capital Commitments, except to the extent prepaid in accordance with Sections 4.12(b)(ii), (iii) and (iv) (Mandatory Prepayment).

(b) Except as set forth in Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement, after the Borrower has delivered a notice of voluntary prepayment in accordance with Section 4.11(a) above, the prepayment date specified in the notice shall be deemed the due date for the principal amount (and the interest thereon) to be paid thereunder and should the Borrower fail to pay any such principal amount and/or interest and/or prepayment premium (if any), in accordance with Section 3.6 (Prepayment Fees and Breakage Costs) of the Common Terms Agreement and Section 5.05 (Funding Losses) due on such date, the Borrower shall pay interest on such overdue amounts in accordance with Section 4.07 (Post-Maturity Interest Rates; Default Interest Rates).

(c) Pursuant to Section 3.7 (Pro Rata Payments) of the Common Terms Agreement and Section 2.3(a)(i)(B) (Payments and Prepayments) of the Common Security and Account Agreement (i) any voluntary prepayment of Working Capital Loans or LC Loans may be made without a voluntary pro rata prepayment of Senior Debt under any other Senior Debt Instrument and (ii) any voluntary prepayment of Senior Debt under any other Senior Debt Instrument may be made without a voluntary pro rata prepayment of Working Capital Loans or LC Loans.

Section 4.12 Mandatory Prepayment.

(a) The Borrower shall prepay, with three (3) Business Days’ prior written notice to the Credit Facility Agent, the Term Loans as and when required under Section 3.4 (Mandatory Prepayments) and Section 3.7 (Pro Rata Payments) of the Common Terms Agreement.

(b) The Borrower shall prepay, with three (3) Business Days’ prior written notice to the Credit Facility Agent, the Working Capital Loans or LC Loans in accordance with Section 3.4 (Mandatory Prepayments) and Section 3.7 (Pro Rata Payments) of the Common Terms Agreement solely in the following circumstances:

(i) other than LC Loans incurred to fund a reimbursement obligation with respect to a drawing under a Letter of Credit, as needed to comply with Section 4.03(a) (Repayment of Working Capital Advances); provided that, for the avoidance of doubt, the Borrower shall not be required to cause any issued and outstanding Letters of Credit to be cancelled or returned;

 

28


(ii) in accordance with Section 3.4(a)(iii) (Mandatory Prepayments – LNG SPA Prepayment Event) of the Common Terms Agreement;

(iii) in accordance with Section 3.4(a)(vi) (Mandatory Prepayments – Illegality) of the Common Terms Agreement as a result of the occurrence of an Illegality Event with respect to a Working Capital Lender; and

(iv) in accordance with Section 3.4(a)(x) (Mandatory Prepayments – Replacement Debt) of the Common Terms Agreement in the event and to the extent the additional debt triggering such prepayment has been incurred to replace such Working Capital Loans and/or LC Loans.

Working Capital Commitments shall be cancelled in the case of the mandatory prepayments set forth in clauses (ii) and (iv) above as provided in Sections 3.4(a)(iii) (Mandatory Prepayments – LNG SPA Prepayment Event) and 3.4(a)(x) (Mandatory Prepayment – Replacement Debt) of the Common Terms Agreement, respectively, and shall be suspended in the case of the mandatory prepayment set forth in clause (iii) above as provided in Section 3.4(a)(vi) (Mandatory Prepayments – Illegality) of the Common Terms Agreement.

(c) Application of Prepayments of Loans to Base Rate Loans and LIBORSOFR Loans. Any prepayment of Loans of a Lender pursuant to this Section 4.12 (Mandatory PrepaymentsPrepayment) shall be applied first to such Lender’s Base Rate Loans to the full extent thereof and second to such Lender’s LIBORSOFR Loans.

Section 4.13 Time and Place of Payments.

(a) Except as provided in Section 3.02(b) (Reimbursement to Issuing Banks), the Borrower shall make each payment (including any payment of principal of or interest on any Loan or any Fees or other Loan Obligations) hereunder without set-off, deduction or counterclaim not later than 12:00 noon New York City time on the date when due in Dollars and, in immediately available funds, to the Credit Facility Agent at the account set forth in Schedule IV (Credit Facility Agent Account Details) or at such other office or account as may from time to time be specified by the Credit Facility Agent to the Borrower. Funds received after 1:00 p.m. New York City time may, at the Credit Facility Agent’s discretion, be deemed to have been received by the Credit Facility Agent on the next succeeding Business Day.

(b) The Credit Facility Agent shall promptly remit in immediately available funds to each Credit Facility Secured Party its share, if any, of any payments received by the Credit Facility Agent for the account of such Credit Facility Secured Party.

(c) Whenever any payment (including any payment of principal of or interest on any Term Loan or any Fees or other Loan obligations) hereunder shall become due, or otherwise would occur, on a day that is not a Business Day, such payment shall (except as otherwise required by the proviso to the definition of “Interest Period” with respect to LIBORSOFR Loans and in the case of the Final Maturity Date, in which case the due date for payment shall be the immediately preceding Business Day) be made on the immediately succeeding Business Day, and such increase of time shall in such case be included in the computation of interest or Fees, if applicable.

 

29


Section 4.14 Advances and Payments Generally.

(a) Except as provided in Section 3.02(b) (Reimbursement to Issuing Banks), unless the Credit Facility Agent has received notice from the Borrower prior to the date on which any payment is due to the Credit Facility Agent for the account of the Lenders or any Issuing Bank hereunder that the Borrower will not make such payment, the Credit Facility Agent may assume that the Borrower has made such payment on such date in accordance with this Agreement and may, in reliance upon such assumption, distribute to the Lenders or the applicable Issuing Bank(s) the amount due. If the Borrower has not in fact made such payment, then each of the Lenders or the applicable Issuing Bank(s) severally agrees to repay to the Credit Facility Agent forthwith on demand the amount so distributed to such Lender in immediately available funds with interest thereon, for each day from (and including) the date such amount is distributed to it to (but excluding) the date of payment to the Credit Facility Agent, at the Federal Funds Effective Rate. A notice of the Credit Facility Agent to any Lender or Issuing Bank with respect to any amount owing under this Section 4.14 (Advances and Payments Generally) shall be conclusive, absent manifest error.

(b) Nothing herein shall be deemed to obligate any Lender or Issuing Bank to obtain funds for any Loan or Letter of Credit reimbursement obligation in any particular place or manner or to constitute a representation by any Lender or Issuing Bank that it has obtained or will obtain funds for any Loan in any particular place or manner.

Section 4.15 Fees.

(a) From and including the Closing Date until the end of the Term Loan Availability Period or with respect to any Term Lender, until the date on which such Term Lender’s Term Loan Commitments are terminated (solely to the extent of such terminated Term Loan Commitments), the Borrower agrees to pay to the Credit Facility Agent, for the account of the Term Lenders, on each CTA Payment Date beginning on the first CTA Payment Date that is also an Interest Payment Date, a commitment fee (a “Term Loan Commitment Fee”) at a rate per annum equal to 35% of the Applicable Margin applicable to LIBORSOFR Loans on the average daily amount by which the Term Loan Commitments exceed the aggregate outstanding principal amount of the Term Loans during the relevant fiscal quarter (or portion thereof) then ended; provided that all Commitment Fees shall be payable in arrears and computed on the basis of the actual number of days elapsed in a year of 360 days, as prorated for any partial quarter, as applicable. Notwithstanding the foregoing, the Borrower will not be required to pay any Commitment Fee to any Term Lender with respect to any period in which such Term Lender was a Defaulting Lender.

(b) From and including the Closing Date until the Working Capital Loan Termination Date, the Borrower agrees to pay to the Credit Facility Agent, for the account of each Working Capital Lender a commitment fee (a “Working Capital Commitment Fee” and, together with the Term Loan Commitment Fee, the “Commitment Fees”) on the daily average amount of such

 

30


Working Capital Lender’s unused Working Capital Commitment at a rate per annum equal to 35% of the Applicable Margin for LIBORSOFR Loans from the date hereof until the Final Maturity Date, payable quarterly in arrears on the last Business Day of each fiscal quarter, commencing on the first such date to occur following the date hereof, and the Working Capital Loan Termination Date. Notwithstanding the foregoing, the Borrower will not be required to pay any Working Capital Commitment Fee to any Working Capital Lender with respect to any period in which such Working Capital Lender was a Defaulting Lender.

(c) The Borrower agrees to pay to the Credit Facility Agent for the account of each Working Capital Lender a letter of credit fee (the “LC Fee”) on (i) the average daily aggregate amount of such Working Capital Lender’s Commitment Percentage of the LC Available Amount, if any, of all Fronted Letters of Credit and (ii) the average daily aggregate amount of the LC Available Amount, if any, of any Non-Fronted Letters of Credit issued by such Working Capital Lender in its capacity as an Issuing Bank, each at a rate per annum equal to the Applicable Margin for LIBORSOFR Loans, payable quarterly in arrears on the last Business Day of each fiscal quarter, commencing on the first such date to occur following the date of issuance of any Letter of Credit hereunder, and on the Working Capital Loan Termination Date; provided, however, that, upon the occurrence and during the continuance of a Loan Facility Event of Default, with respect to any outstanding Letters of Credit which are not cash collateralized pursuant to Section 9.05 (Application of Proceeds), such LC Fee shall be increased by 2.0% per annum.

(d) The Borrower agrees to pay to each Issuing Bank a letter of credit fronting fee (the “Fronting Fee”) in an amount equal to 0.20% per annum of the aggregate LC Available Amount of each Fronted Letter of Credit issued by such Issuing Bank, payable quarterly in arrears on the last Business Day of each fiscal quarter, commencing on the first such date to occur following the date of issuance of such Letter of Credit hereunder, and on the Working Capital Loan Termination Date.

(e) The Borrower agrees to pay or cause to be paid to the Credit Facility Agent for the account of the Lenders and the Credit Facility Agent, additional fees in the amounts and at the times from time to time agreed to by the Borrower and the Credit Facility Agent, including pursuant to each fee letter with an Initial Coordinating Lead Arranger, Coordinating Lead Arranger or Documentation Bank and any other fee letters entered into by the Borrower with any of the Lenders from time to time in respect of the Credit Facility Agreement.

(f) All Fees shall be paid on the dates due in immediately available funds. Once paid, none of the Fees shall be refundable under any circumstances.

(g) All Commitment Fees, Fronting Fees and LC Fees shall be computed on the basis of 360-day year, as prorated for any partial quarter, as applicable.

(h) The Borrower shall not be liable to pay any Lender or Issuing Bank any upfront fees, fronting fees or agent fees, nor shall it be liable to pay any other fees, costs, expenses or charges with respect to the transactions contemplated under this Agreement, other than as may be specifically stated in this Agreement, the Fee Letters or any other agreement in writing between such Lender or Issuing Bank and the Borrower.

 

31


Section 4.16 Pro Rata Treatment.

(a) The portion of any Type of Loan or Advance made shall be allocated by the Credit Facility Agent among the applicable Lenders such that, following each Loan or Advance, the ratio of each Lender’s outstanding Commitments of such Type to the outstanding Aggregate Commitment of such Type is equal to each Lender’s respective Commitment Percentage of such Type.

(b) Except as otherwise provided in Section 5.01 (LIBOR Lending UnlawfulIllegality), each reduction of Commitments of any Type, pursuant to Section 2.07 (Termination or Reduction of Commitments) or otherwise, shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with, and subject to the exceptions in, Section 2.07 (Termination or Reduction of Commitments) and Section 3.8 (Reductions and Cancellations of Facility Debt Commitments) of the Common Terms Agreement. Each reduction in Issuing Bank Limits shall be allocated by the Credit Facility Agent pro rata among the Issuing Banks.

(c) Except as otherwise required under Section 3.7 (Pro Rata Payment) of the Common Terms Agreement and Section 4.11 (Voluntary Prepayment), Section 4.12 (Mandatory Prepayment) or Article V (LIBOR AndSOFR and Tax Provisions), (i) each payment or prepayment of principal of a Type of Loans shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with the respective principal amounts of their outstanding Loans of such Type (other than Defaulting Lenders), (ii) each payment of interest on a Type of Loans shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with the respective interest amounts outstanding on their Loans of such Type (other than Defaulting Lenders) and (iii) each payment of the Commitment Fees shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with their respective Term Loan Commitments or Working Capital Commitments (other than Defaulting Lenders), as applicable.

Section 4.17 Sharing of Payments.

(a) If any Lender or Issuing Bank obtains any payment or other recovery (whether voluntary, involuntary, by application of setoff or otherwise) on account of any Type of Loan (other than pursuant to the terms of Article V (LIBOR AndSOFR and Tax Provisions) or Section 4.16 (Pro Rata Treatment)) in excess of its pro rata share of payments then or therewith obtained by all Lenders holding Loans of such Type, such Lender or Issuing Bank shall purchase from the other applicable Lenders (for cash at face value) such participations in Loans of such Type made by them as shall be necessary to cause such purchasing Lender to share the excess payment or other recovery ratably with each of them; provided, however, that, if all or any portion of the excess payment or other recovery is thereafter recovered from such purchasing Lender or Issuing Bank, the purchase shall be rescinded and each Lender that has sold a participation to the purchasing Lender or Issuing Bank shall repay to the purchasing Lender or

 

32


Issuing Bank the purchase price to the ratable extent of such recovery together with an amount equal to such selling Lender’s ratable share (according to the proportion of (x) the amount of such selling Lender’s required repayment to the purchasing Lender or Issuing Bank to (y) the total amount so recovered from the purchasing Lender or Issuing Bank) of any interest or other amount paid or payable by the purchasing Lender or Issuing Bank in respect of the total amount so recovered. The Borrower agrees that any Lender or Issuing Bank so purchasing a participation from another Lender pursuant to this Section 4.17(a) (Sharing of Payments) may, to the fullest extent permitted by law, exercise all its rights of payment (including pursuant to Section 11.13 (Right of Set-offSet-Off)) with respect to such participation as fully as if such Lender or Issuing Bank were the direct creditor of the Borrower in the amount of such participation. The provisions of this Section shall not be construed to apply to any payment by the Borrower pursuant to and in accordance with the express terms of this Agreement or any payment obtained by any Lender as consideration for the assignment or sale of a participation in any of its Loans.

(b) If under any applicable bankruptcy, insolvency or other similar law, any Lender receives a secured claim in lieu of a setoff to which this Section 4.17 (Sharing of Payments) applies, such Lender shall, to the extent practicable, exercise its rights in respect of such secured claim in a manner consistent with the rights of the Lenders entitled under this Section 4.17 (Sharing of Payments) to share in the benefits of any recovery on such secured claim.

Section 4.18 Defaulting Lenders.

(a) Notwithstanding anything to the contrary contained in this Agreement, if any Lender becomes a Defaulting Lender, then, until such time as such Lender is no longer a Defaulting Lender, to the extent permitted by applicable Law, any payment of principal, interest, fees or other amounts received by the Credit Facility Agent for the account of such Defaulting Lender (whether voluntary or mandatory, at maturity, pursuant to Article IX (Default and Enforcement) or otherwise) shall be applied at such time or times as may be determined by the Credit Facility Agent as follows: first, to the payment of any amounts owing by such Defaulting Lender to the Credit Facility Agent hereunder or under any other Finance Document; second, to the payment on a pro rata basis of any amounts owing by such Defaulting Lender to any Issuing Bank hereunder; third, to cash collateralize the Issuing Banks’ Fronting Exposure, if any, with respect to such Defaulting Lender in accordance with the procedures set forth in Section 9.03(a) (Action Upon Event of Default); fourth, as the Borrower may request (so long as no Loan Facility Event of Default or Unmatured Loan Facility Event of Default exists), to the funding of any Advance or Loan in respect of which such Defaulting Lender has failed to fund its portion thereof as required by this Agreement, as determined by the Credit Facility Agent; fifth, if so determined by the Credit Facility Agent and the Borrower, to be held in a deposit account and released pro rata in order to (x) satisfy such Defaulting Lender’s potential future funding obligations with respect to Advances or Loans under this Agreement and (y) cash collateralize the Issuing Banks’ future Fronting Exposure, if any, with respect to such Defaulting Lender with respect to future Letters of Credit issued under this Agreement in accordance with the procedures set forth in Section 9.03(a) (Action Upon Event of Default); sixth, to the payment of any amounts owing to the Lenders or the Issuing Banks as a result of any judgment of a court of competent jurisdiction obtained by any Lender or any Issuing Bank against such Defaulting Lender as a

 

33


result of such Defaulting Lender’s breach of its obligations under this Agreement; seventh, so long as no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is continuing, to the payment of any amounts owing to the Borrower as a result of any judgment of a court of competent jurisdiction obtained by the Borrower against such Defaulting Lender as a result of such Defaulting Lender’s breach of its obligations under this Agreement; and eighth, to such Defaulting Lender or as otherwise directed by a court of competent jurisdiction; provided that, if (x) such payment is a payment of the principal amount of any Loans in respect of which such Defaulting Lender has not fully funded its appropriate share, and (y) such Loans were made or the related Letters of Credit were issued at a time when the conditions set forth in Section 7.01 (Conditions to Closing), Section 7.02 (Conditions to Each Term Loan Advance) or Section 7.03 (Conditions to Each Working Capital Advance), as applicable, were satisfied or waived, such payment shall be applied solely to pay the Loans owed to all Non-Defaulting Lenders on a pro rata basis prior to being applied to the payment of any Loans owed to such Defaulting Lender until such time as all Loans and funded and unfunded participations in Letters of Credit are held by the Lenders pro rata in accordance with their applicable Commitments without giving effect to Section 4.18(b). Any payments, prepayments or other amounts paid or payable to a Defaulting Lender that are applied (or held) to pay amounts owed by a Defaulting Lender or to post cash collateral pursuant to this Section 4.18 shall be deemed paid to and redirected by such Defaulting Lender, and such Defaulting Lender irrevocably consents hereto.

(b) All or any part of such Defaulting Lender’s participation in LC Exposure shall be reallocated pro rata among the Non-Defaulting Lenders in accordance with their respective Commitment Percentages (calculated without regard to such Defaulting Lender’s Working Capital Commitment) but only to the extent that (i) the conditions set forth in Section 4.3(c) (Conditions to Each Advance under the Working Capital Facility – Absence of Default) and Section 4.3(d) (Conditions to Each Advance under the Working Capital Facility – Representations and Warranties) of the Common Terms Agreement are satisfied at the time of such reallocation, and (ii) such reallocation does not cause the sum of the outstanding principal amount of the Working Capital Loans, LC Loans and the LC Exposure of any Non-Defaulting Lender to exceed such Non-Defaulting Lender’s Working Capital Commitment. No reallocation hereunder shall constitute a waiver or release of any claim of any party hereunder against a Defaulting Lender arising from that Lender having become a Defaulting Lender, including any claim of a Non-Defaulting Lender as a result of such Non-Defaulting Lender’s increased exposure following such reallocation. If the reallocation described in this Section 4.18(b) cannot, or can only partially, be effected, the Borrower shall, without prejudice to any right or remedy available to it hereunder or under law, cash collateralize the Issuing Banks’ Fronting Exposure on account of such Defaulting Lender (after giving effect to partial reallocations) in accordance with the procedures set forth in Section 9.03(a) (Action Upon Event of Default); provided that, the Borrower shall have sixty (60) days from receipt of written notice by the Credit Facility Agent that the reallocation described in this Section 4.18(b) cannot, or can only partially, be effected, to cash collateralize the Issuing Banks’ Fronting Exposure in accordance with this Section 4.18(b), so long as no Loan Facility Event of Default shall have occurred and be continuing during such period.

 

34


(c) If the Borrower, the Credit Facility Agent and the Issuing Banks agree in writing that a Lender is no longer a Defaulting Lender, the Credit Facility Agent will so notify the parties hereto, whereupon as of the effective date specified in such notice and subject to any conditions set forth therein (which may include arrangements with respect to any cash collateral), that Lender will, to the extent applicable, purchase at par that portion of outstanding Loans of the other Lenders or take such other actions as the Credit Facility Agent may determine to be necessary to cause the Loans and funded and unfunded participations in Letters of Credit to be held pro rata by the Lenders in accordance with the relative amounts of their applicable Commitments (without giving effect to Section 4.18(b)), whereupon such Lender will cease to be a Defaulting Lender; provided that, no adjustments will be made retroactively with respect to fees accrued or payments made by or on behalf of the Borrower while that Lender was a Defaulting Lender; and provided further that, except to the extent otherwise expressly agreed by the affected parties, no change hereunder from Defaulting Lender to Non-Defaulting Lender will constitute a waiver or release of any claim of any party hereunder arising from that Lender’s having been a Defaulting Lender.

(d) So long as any Lender is a Defaulting Lender, no Issuing Bank shall be required to issue, amend, extend, renew or increase any Letter of Credit to the extent the reallocation described in Section 4.18(b) cannot be effected or the Borrower has not cash collateralized such Issuing Bank’s Fronting Exposure with respect to such Defaulting Lender.

ARTICLE V

LIBORSOFR AND TAX PROVISIONS

Section 5.01 LIBOR Lending UnlawfulIllegality. In the event that it becomes unlawful or, by reason of a Change in Law, any Lender is prohibited from making or maintaining LIBOR Loans, then such Lender will promptly notify the Borrower of such event (with a copy to the Credit Facility Agent and Intercreditor Agent) and such Lender’s obligation to make or to continue LIBOR Loans, or to convert Base Rate Loans into LIBOR Loans, as the case may be, shall be suspended until such time as such Lender is not prohibited from making and maintaining LIBOR Loans. During such period of suspension, the Loans that would otherwise be made by such Lender as LIBOR Loans shall be made instead by such Lender as Base Rate Loans and each LIBOR Loan made by such Lender and outstanding will automatically, on the last day of the then existing Interest Period therefor if such Loan may lawfully remain outstanding until the end of such Interest Period, and otherwise immediately, convert into a Base Rate Loan. At the Borrower’s request, each Lender shall use reasonable efforts, including using reasonable efforts to designate a different lending office for funding or booking its Loans or to assign its rights and obligations under the Finance Documents to another of its offices, branches or Affiliates, if, in the reasonable judgment of such Lender, such designation or assignment (i) would eliminate or avoid such illegality and (ii) would not subject such Lender to any unreimbursed cost or expense and would not otherwise be disadvantageous to such Lender. The Borrower shall pay all reasonable costs and expenses incurred by any Lender in connection with any such designation or assignment.

 

35


. If any Lender determines that any applicable law has made it unlawful, or that any Governmental Authority has asserted that it is unlawful, for any Lender or its applicable lending office to make, maintain or fund Loans whose interest is determined by reference to SOFR, the Term SOFR Reference Rate, Adjusted Term SOFR or, Term SOFR, or to determine or charge interest based upon SOFR, the Term SOFR Reference Rate, Adjusted Term SOFR or Term SOFR, then, upon notice thereof by such Lender to the Borrower (through the Credit Facility Agent) (an “Illegality Notice”), (a) any obligation of the Lenders to make SOFR Loans, and any right of the Borrower to continue SOFR Loans or to convert Base Rate Loans to SOFR Loans, shall be suspended, and (b) the interest rate on which Base Rate Loans shall, if necessary to avoid such illegality, be determined by the Credit Facility Agent without reference to clause (c) of the definition of “Base Rate,” in each case, until each affected Lender notifies the Credit Facility Agent and the Borrower that the circumstances giving rise to such determination no longer exist. Upon receipt of an Illegality Notice, the Borrower shall, if necessary to avoid such illegality, upon demand from any Lender (with a copy to the Credit Facility Agent), prepay or, if applicable, convert all SOFR Loans to Base Rate Loans (the interest rate on which Base Rate Loans shall, if necessary to avoid such illegality, be determined by the Credit Facility Agent without reference to clause (c) of the definition of “Base Rate”), on the last day of the Interest Period therefor, if all affected Lenders may lawfully continue to maintain such SOFR Loans to such day, or immediately, if any Lender may not lawfully continue to maintain such SOFR Loans to such day, in each case until the Credit Facility Agent is advised in writing by each affected Lender that it is no longer illegal for such Lender to determine or charge interest rates based upon SOFR, the Term SOFR Reference Rate or Term SOFR. Upon any such prepayment or conversion, the Borrower shall also pay accrued interest on the amount so prepaid or converted, together with any additional amounts required pursuant to Section 5.05 (Funding Losses).

Section 5.02 Inability to Determine LIBORApplicable Interest Rate. IfSubject to Section 5.07 (Replacement Benchmark Setting), if, on or prior to the commencementfirst day of any Interest Period for a LIBORany SOFR Loan:

(a) the Credit Facility Agent reasonably determines that adequate and reasonable means do not exist for ascertaining LIBOR for such Interest Period; or(which determination shall be conclusive and binding absent manifest error) that “Adjusted Term SOFR” cannot be determined pursuant to the definition thereof, or

(b) the Credit Facility Agent is advised by the Required Lenders that such Required Lenders have reasonably determined that LIBOR for suchdetermine that for any reason in connection with any request for a SOFR Loan or a conversion thereto or a continuation thereof that Adjusted Term SOFR for any requested Interest Period willwith respect to a proposed SOFR Loan does not adequately and fairly reflect the cost to such Lenders of making orand maintaining their LIBOR Loans for such Interest Period;such SOFR Loan, and the Required Lenders have provided notice of such determination to the Credit Facility Agent,

 

36


then the Credit Facility Agent shall give notice thereof to the Borrower and the Lenders by telephone or telecopy as promptly as practicable thereafter and, until the Credit Facility Agent notifies the Borrower and the Lenders that the circumstances giving rise to such notice no longer exist (which notice of subsequent change in circumstances shall be given as promptly as practicable), (i) any Interest Period Notice that requests the conversion of any Loan to, or continuation of any Loan as, a LIBOR Loan shall be ineffective and such Loan shall be converted to a Base Rate Loan on the last day of the Interest Period applicable thereto, and (ii) if any Disbursement Request requests a LIBOR Loan, such Loan shall be made as a Base Rate Loan, or, at the election of the Borrower (upon receipt of the determination to be made by the Required Lenders and only if they are able to agree on such a determination), made as a Loan bearing interest at such rate as the Required Lenders shall determine adequately reflects the costs to the Lenders of making such Loans. The Credit Facility Agent shall promptly give notice to the Borrower, the Lenders and the Intercreditor Agent when the circumstances that gave rise to such notice no longer exist and, in such event, any outstanding Base Rate Loans may be converted, on the last day of the then current Interest Period, to LIBOR Loans.

the Credit Facility Agent will promptly so notify the Borrower and each Lender.

Upon notice thereof by the Credit Facility Agent to the Borrower, any obligation of the Lenders to make SOFR Loans, and any right of the Borrower to continue SOFR Loans or to convert Base Rate Loans to SOFR Loans, shall be suspended (to the extent of the affected SOFR Loans or affected Interest Periods) until the Credit Facility Agent (with respect to clause (b) above, at the instruction of the Required Lenders) revokes such notice. Upon receipt of such notice, (i) the Borrower may revoke any pending request for a borrowing of, conversion to or continuation of SOFR Loans (to the extent of the affected SOFR Loans or affected Interest Periods) or, failing that, the Borrower will be deemed to have converted any such request into a request for a borrowing of or conversion to Base Rate Loans in the amount specified therein and (ii) any outstanding affected SOFR Loans will be deemed to have been converted into Base Rate Loans at the end of the applicable Interest Period. Upon any such conversion, the Borrower shall also pay accrued interest on the amount so converted, together with any additional amounts required pursuant to Section 5.05 (Funding Losses). Subject to Section 5.07 (Replacement Benchmark Setting), if the Credit Facility Agent determines (which determination shall be conclusive and binding absent manifest error) that “Adjusted Term SOFR” cannot be determined pursuant to the definition thereof on any given day, the interest rate on Base Rate Loans shall be determined by the Credit Facility Agent without reference to clause (c) of the definition of “Base Rate” until the Credit Facility Agent revokes such determination.

Section 5.03 Increased Costs.

(a) If any Lender or Issuing Bank incurs additional costs or suffers a reduction, in each case, as described in Section 22.1(a) (Increased Costs) of the Common Terms Agreement, the Borrower shall compensate such Lender or Issuing Bank in accordance with Section 22.1(a) (Increased Costs) of the Common Terms Agreement (except to the extent the Borrower is excused from payment pursuant to Section 5.04 (Obligation to Mitigate)). In determining the amount of such compensation, such Lender or Issuing Bank may, subject to Section 22.1(e) (Increased Costs) of the Common Terms Agreement, use any method of averaging and attribution that it (in its sole discretion) shall deem appropriate.

 

37


(b) If any Lender or Issuing Bank or Lender’s or Issuing Bank’s holding company has suffered or would suffer a reduced rate of return as described in Section 22.1(b) (Increased Costs) of the Common Terms Agreement, the Borrower shall compensate such Lender or Issuing Bank or (without duplication) such Lender’s or Issuing Bank’s holding company in accordance with Section 22.1(b) (Increased Costs) of the Common Terms Agreement (except to the extent the Borrower is excused from payment pursuant to Section 5.04 (Obligation to Mitigate)).

(c) To claim any amount under this Section 5.03 (Increased Costs), the Credit Facility Agent or a Lender or Issuing Bank, as applicable, shall promptly deliver a certificate in accordance with Section 22.1(c) (Increased Costs) of the Common Terms Agreement (with a copy to the Credit Facility Agent, if delivered by a Lender or Issuing Bank). The Borrower shall pay the Credit Facility Agent or Lender or Issuing Bank, as applicable, in accordance with Section 22.1(c) (Increased Costs) of the Common Terms Agreement.

(d) Promptly after the Credit Facility Agent or Lender or Issuing Bank, as applicable, has determined that it will make a request for increased compensation pursuant to this Section 5.03 (Increased Costs), such Person shall notify the Borrower thereof (with a copy to the Credit Facility Agent and the Intercreditor Agent). Failure or delay on the part of the Credit Facility Agent or Lender or Issuing Bank to demand compensation pursuant to this Section 5.03 (Increased Costs) shall not constitute a waiver of such Person’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Person pursuant to this Section 5.03 (Increased Costs) for any increased costs or reductions outside of the period referred to in Section 22.1(d) (Increased Costs) of the Common Terms Agreement.

(e) Notwithstanding any other provision in this Agreement, no Lender or Issuing Bank shall demand compensation pursuant to this Section 5.03 (Increased Costs) in the circumstances described in Section 22.1(e) (Increased Costs) of the Common Terms Agreement.

Section 5.04 Obligation to Mitigate.

(a) If any Lender or Issuing Bank requests compensation under Section 5.03 (Increased Costs), or if the Borrower is required to pay any additional amount to any Lender or Issuing Bank or any Governmental Authority for the account of any Lender or Issuing Bank pursuant to Section 5.06 (Taxes), then such Lender or Issuing Bank shall have an obligation to mitigate such compensation in accordance with Section 19.5(a) (Mitigation Obligations; Replacement of Lenders) of the Common Terms Agreement.

(b) The Borrower may require a Lender or Issuing Bank to assign and delegate (in accordance with and subject to the restrictions contained in Section 11.04 (Assignments)) its interests, rights and obligations under this Agreement and the related Finance Documents in accordance with Section 19.5(c) (Mitigation Obligations; Replacement of Lenders) of the Common Terms Agreement. Nothing in this SectionSection 5.04 (Obligation to Mitigate) shall be deemed to prejudice any rights that the Borrower, the Credit Facility Agent or any Lender or any Issuing Bank may have against any Lender or Issuing Bank that is a Defaulting Lender. Notwithstanding anything in this section toSection 5.04 (Obligation to Mitigate) to the contrary, any Working Capital Lender that acts as an Issuing Bank may not be replaced hereunder at any

 

38


time it has any Letter of Credit outstanding hereunder unless arrangements satisfactory to such Working Capital Lender (including the furnishing of a backstop standby letter of credit in form and substance, and issued by an issuer, reasonably satisfactory to such Issuing Bank and/or the depositing of cash collateral into a cash collateral account in amounts and pursuant to arrangements reasonably satisfactory to such Issuing Bank) have been made with respect to such outstanding Letter of Credit.

Section 5.05 Funding Losses. In the event of (a) the payment of any principal of any LIBOR Loan other than on the last day of an Interest Period applicable thereto (including as a result of a Loan Facility Event of Default), (b) the conversion of any LIBOR Loan other than on the last day of the Interest Period applicable thereto, (c) the failure to borrow, convert, continue or prepay any LIBOR Loan on the date specified in any notice delivered pursuant hereto (other than through any default by the relevant Lender seeking reimbursement) or (d) the assignment of any LIBOR Loan other than on the last day of the Interest Period applicable thereto as a result of a request by the Borrower pursuant to Section 5.04 (Obligation to Mitigate) (a “Breakage Event”), then, in any such event, the Borrower shall compensate each Lender for the Breakage Costs. Such Breakage Costs shall be determined by the Credit Facility Agent based upon the information delivered to it by such Lender. To claim any amount under this Section 5.05 (Funding Losses), the Credit Facility Agent shall promptly deliver to the Borrower a certificate setting forth in reasonable detail any amount or amounts that the applicable Lender is entitled to receive pursuant to this Section 5.05 (Funding Losses) (including calculations, in reasonable detail, showing how the Credit Facility Agent computed such amount or amounts), which certificate shall be based upon the information delivered to the Credit Facility Agent by such Lender. The Borrower shall pay to the Credit Facility Agent for the benefit of the applicable Lender the amount due and payable and set forth on any such certificate within 30 days after receipt thereof.

. The Borrower shall compensate each Lender, upon written request by such Lender (which request shall set forth the basis for requesting such amounts in reasonable detail), for all reasonable losses, expenses and liabilities (including any interest paid or payable by such Lender to Lenders of funds borrowed by it to make or carry its SOFR Loans and any loss, expense or liability sustained by such Lender in connection with the liquidation or re-employment of such funds but excluding loss of anticipated profits) which such Lender may sustain: (a) if for any reason (other than a default by such Lender) a borrowing of any SOFR Loan does not occur on a date specified therefor in a Disbursement Request or other written request for borrowing, or a conversion to or continuation of any SOFR Loan does not occur on a date specified therefor in an Interest Period Notice or a written request for conversion or continuation; (b) if any prepayment or other principal payment of, or any conversion of, any of its SOFR Loans occurs on a date prior to the last day of an Interest Period applicable to that Loan; (c) if any prepayment of any of its SOFR Loans is not made on any date specified in a notice of prepayment given by the Borrower; or (d) if any SOFR Loan is converted other than on the last day of the Interest Period applicable thereto (including as a result of a Loan Facility Event of Default)..

 

39


Section 5.06 Taxes. Any and all payments on account of any Loan Obligations shall be made in accordance with the provisions of Article 21 (Tax Gross-up and Indemnities) of the Common Terms Agreement.

Section 5.07 Effect ofReplacement Benchmark Transition EventSetting.

(a) Benchmark Replacement.

(i) Notwithstanding anything to the contrary herein or in any other Finance Document, upon the occurrence of a Benchmark Transition Event or an Early Opt-in Election, as applicable, the Credit Facility Agent and the Borrower may amend this Agreement to replace LIBORthe then-current Benchmark with a Benchmark Replacement. Any such amendment with respect to a Benchmark Transition Event will become effective at 5:00 p.m. (New York City time) on the fifth (5th) Business Day after the Credit Facility Agent has posted such proposed amendment to all affected Lenders and the Borrower so long as the Credit Facility Agent has not received, by such time, written notice of objection to such amendment from Lenders comprising the Required Lenders. Any such amendment with respect to an Early Opt-in Election will become effective on the date that Lenders comprising the Required Lenders have delivered to the Credit Facility Agent written notice that such Required Lenders accept such amendment. No replacement of LIBORa Benchmark with a Benchmark Replacement pursuant to this Section 5.07 (Effect of (a)(i) (Benchmark Transition EventReplacement) will occur prior to the applicable Benchmark Transition Start Date.

(ii) No Interest Rate Hedging Instrument shall be deemed to be a “Finance Document” for purposes of this Section 5.07(a)(ii) (Benchmark Replacement).

(b) Benchmark Replacement Conforming Changes. In connection with the use, administration, adoption or implementation of a Benchmark Replacement, the Credit Facility Agent, with the written consent of the Borrower (such consent not to be unreasonably withheld, conditioned or delayed), will have the right to make Benchmark Replacement Conforming Changes from time to time and, notwithstanding anything to the contrary herein or in any other Finance Document, any amendments implementing such Benchmark Replacement Conforming Changes will become effective without any further action or consent of any other party to this Agreement or any other Finance Document.

(c) Notices; Standards for Decisions and Determinations. The Credit Facility Agent will promptly notify the Borrower and the Lenders of (i) any occurrence of a Benchmark Transition Event or an Early Opt-in Election, as applicable, and its related Benchmark Replacement Date and Benchmark Transition Start Date, (ii) the implementation of any Benchmark Replacement, and (iiiii) the effectiveness of any Benchmark Replacement Conforming Changes in connection with the use, administration, adoption or implementation of a Benchmark Replacement. The Credit Facility Agent will promptly notify the Borrower of (A) the removal or reinstatement of any tenor of a Benchmark pursuant to Section 5.07(d) (Unavailability of Tenor Benchmark), and (ivB) the commencement or conclusion of any Benchmark Unavailability Period. Any determination, decision or election that may be made by

 

40


the Credit Facility Agent or, if applicable, any Lender (or group of Lenders) pursuant to this Section 5.07 (Effect ofReplacement Benchmark Transition EventSetting) including any determination with respect to a tenor, rate or adjustment or of the occurrence or non-occurrence of an event, circumstance or date and any decision to take or refrain from taking any action or any selection, will be conclusive and binding absent manifest error and may be made in its or their sole discretion and without consent from any other party heretoto this Agreement or any other Finance Document, except, in each case, as expressly required pursuant to this Section 5.07 (Effect ofReplacement Benchmark Transition EventSetting).

(d) Unavailability of Tenor of Benchmark. Notwithstanding anything to the contrary herein or in any other Finance Document, at any time (including in connection with the implementation of a Benchmark Replacement), (i) if the then-current Benchmark is a term rate (including the Term SOFR Reference Rate) and either (A) any tenor for such Benchmark is not displayed on a screen or other information service that publishes such rate from time to time as selected by the Credit Facility Agent in its reasonable discretion or (B) the administrator of such Benchmark or the regulatory supervisor for the administrator of such Benchmark has provided a public statement or publication of information announcing that any tenor for such Benchmark is not or will not be representative then the Credit Facility Agent may modify the definition of Interest Period (or any similar or analogous definition) for any Benchmark settings at or after such time to remove such unavailable, non-representative, non-compliant or non-aligned tenor and (ii) if a tenor that was removed pursuant to clause (i) above either (A) is subsequently displayed on a screen or information service for a Benchmark (including a Benchmark Replacement) or (B) is not, or is no longer, subject to an announcement that it is not or will not be representative for a Benchmark (including a Benchmark Replacement), then the Credit Facility Agent may modify the definition of “Interest Period” (or any similar or analogous definition) for all Benchmark settings at or after such time to reinstate such previously removed tenor.

(e) (d) Benchmark Unavailability Period. Upon the Borrower’s receipt of notice of the commencement of a Benchmark Unavailability Period, the Borrower may revoke any pending request for an Advancea SOFR borrowing of, conversion to or continuation of LIBORSOFR Loans to be made, converted or continued during any Benchmark Unavailability Period and, failing that, the Borrower will be deemed to have converted any such request into a request for an Advancea borrowing of or conversion to Base Rate Loans. During anya Benchmark Unavailability Period or at any time that a tenor for the then-current Benchmark is not an Available Tenor, the component of the Base Rate based upon LIBORthe then-current Benchmark or such tenor for such Benchmark, as applicable, will not be used in any determination of the Base Rate.

ARTICLE VI

REPRESENTATIONS AND WARRANTIES

Section 6.01 Incorporation of Common Terms Agreement. The representations and warranties of the Obligors set forth in Article 5 (Representations and Warranties of Obligors) of the Common Terms Agreement have been made to and for the benefit of each of the Lenders and shall apply mutatis mutandis to this Article VI as if fully set forth herein.

 

41


ARTICLE VII

CONDITIONS PRECEDENT

Section 7.01 Conditions to Closing. The occurrence of the Closing, the effectiveness of the Lenders’ Commitments, the obligation of each of the Lenders to make available its Initial Advance and the obligation of the Issuing Banks to issue any Letters of Credit on the Closing Date shall be subject to the satisfaction (or waiver by each of the Lenders and each of the Issuing Banks) of each of the conditions precedent set forth in Section 4.1 (Conditions to Closing Date and Initial Advance) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.01 (Conditions to Closing) as if fully set forth herein.

Section 7.02 Conditions to Each Term Loan Advance. The obligation of each Term Lender to make any Advance of Term Loans (whether from the Base Term Loan Commitment or Contingency Reserve Term Loan Commitment) shall be subject to the satisfaction (or waiver by the Credit Facility Agent acting on the instruction of the Required Term Lenders), prior to the making of such Advance, of each of the conditions precedent (and in the case of any Advance of Term Loans other than the Initial Advance, no others) set forth in Section 4.2 (Conditions to Each Advance) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.02 (Conditions to Each Term Loan Advance) as if fully set forth herein.

Section 7.03 Conditions to Each Working Capital Advance. The obligation of (i) any Issuing Bank to issue Letters of Credit (or extend the maturity thereof (other than any automatic extension thereunder) or modify or amend the terms thereof) and (ii) the Working Capital Lenders to make available Working Capital Loans, in each case, subsequent to the Closing Date is subject to the satisfaction (or waiver by the Credit Facility Agent acting on the instruction of the Required Working Capital Lenders and the relevant Issuing Banks, as applicable), prior to issuing such Letter of Credit (or extension, modification or amendment thereof) or to the making of such Working Capital Advance, of each of the conditions precedent set forth in Section 4.3 (Conditions to Each Advance under the Working Capital Facility) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.03 (Conditions to Each Working Capital Advance) as if fully set forth herein.

Section 7.04 Conditions to Occurrence of the Project Completion Date.

The occurrence of the Project Completion Date is subject to the satisfaction of each of the conditions (or waiver by the Credit Facility Agent acting on the instruction of the Required Lenders) of the conditions precedent set forth in Section 14.1 (Conditions to Occurrence of the Project Completion Date) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.04 (Conditions to Occurrence of the Project Completion Date) as if fully set forth herein.

 

42


ARTICLE VIII

COVENANTS

Section 8.01 Covenants. The covenants of the Obligors set forth in Article 6 (Incurrence of Additional Senior Debt), Article 7 (Permitted Development Expenditures/Expansions), Article 8 (LNG SPA Covenants), Article 9 (Material Construction Contracts), Article 10 (Reporting by the Borrower), Article 11 (Restricted Payments), Article 12 (Obligors Covenants), Article 13 (Consultants), Section 14.2 (Project Completion Date Waterfall) and Article 20 (Subordination) the Common Terms Agreement have been made to and for the benefit of each of the Lenders and shall apply mutatis mutandis to this Article VIII as if fully set forth herein.

ARTICLE IX

DEFAULT AND ENFORCEMENT

Section 9.01 Events of Default. The occurrence of any Loan Facility Event of Default under the Common Terms Agreement shall constitute an event of default under this Agreement, subject to all of the relevant provisions of the Common Terms Agreement.

Section 9.02 Acceleration Upon Bankruptcy. If any Loan Facility Event of Default described in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement occurs, all outstanding Commitments, if any, shall automatically terminate and the outstanding principal amount of the outstanding Loans and all other Loan Obligations shall automatically be and become immediately due and payable, in each case without notice, demand or further act of the Credit Facility Agent, the Lenders, the Intercreditor Agent, the Collateral Agent or any other Credit Facility Secured Party in accordance with Section 16.1(b) (Facility Lender Remedies for Loan Facility Declared Events of Default—Initiating Percentage for Enforcement Action with Respect to Collateral) of the Common Terms Agreement.

Section 9.03 Action Upon Event of Default.

(a) If any Loan Facility Event of Default under the Common Terms Agreement or this Agreement occurs and is Continuing, the Lenders and the Issuing Banks may, by decision of the Required Lenders (i) instruct the Credit Facility Agent, as Senior Creditor Group Representative for the Lenders and the Issuing Banks, to further instruct the Intercreditor Agent to declare that a Loan Facility Declared Default has occurred under this Agreement in accordance with Section 15.2(a) (Declaration of Loan Facility Declared Default) of the Common Terms Agreement and (ii) thereafter, subject to the Intercreditor Agreement and the Common Security and Account Agreement, exercise, or instruct the Intercreditor Agent to exercise, any Enforcement Action provided under Section 16.1 (Facility Lender Remedies for Loan Facility Declared Events of Default) of the Common Terms Agreement (including, subject

 

43


to the Common Terms Agreement and the Common Security and Account Agreement, requiring the Borrower to deposit with the Credit Facility Agent an amount in the LC Cash Collateral Account equal to one hundred two percent (102%) of the amount available to be drawn under all Letters of Credit then outstanding), each of which is incorporated by reference and shall apply mutatis mutandis to this Section 9.03 (Action Upon Event of Default) as if fully set forth herein; provided that nothing herein shall, upon the occurrence of a Loan Facility Event of Default under Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement, require any certification, declaration or other notice prior to the deemed declaration of such Loan Facility Declared Default or the acceleration of the Loans in connection with the occurrence thereof as provided under Section 16.1(b) (Facility Lender Remedies for Loan Facility Declared Events of Default—Initiating Percentage for Enforcement Action with Respect to Collateral) of the Common Terms Agreement.

(b) Subject to Section 10.5 (Certain Agreements with Respect to Bankruptcy) of the Common Security and Account Agreement, following commencement of any Bankruptcy Proceeding by or against either Obligor or Pledgor any Lender may: (1) file a claim or statement of interest with respect to (and to the extent of) the Senior Debt Obligations (if any) owed by such person to such Lender or Issuing Bank in accordance with the Finance Documents, (2) vote on any plan of reorganization and (3) make other filings, arguments, objections and motions in connection with such Bankruptcy Proceeding, in each case in accordance with the terms of the Finance Documents (other than any requirement for an intercreditor vote to take such action).

(c) Any termination and acceleration made pursuant to this Section 9.03 (Action Upon Event of Default) and Section 16.1(a)(ii) (Facility Lender Remedies for Loan Facility Declared Event of Default – Enforcement Action) of the Common Terms Agreement may, should the Required Lenders in their sole and absolute discretion so elect, be rescinded by written notice to the Borrower at any time after the principal of the Loans has become due and payable, but before any judgment or decree for the payment of the monies so due, or any part thereof, has been entered; provided that, no such rescission or annulment shall extend to or affect any subsequent Loan Facility Event of Default or impair any right consequent thereon.

(d) An event of default under this Credit Facility Agreement shall be deemed to be declared, in respect of any Loan Facility Event of Default referred to in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement, immediately and automatically upon its occurrence, without the requirement for any certification, declaration or other notice from an Term Lender or the Intercreditor Agent or any Senior Creditor in accordance with Section 15.2(a) (Declaration of Loan Facility Declared Default) of the Common Terms Agreement.

(e) Promptly after any Lender obtains knowledge of any Loan Facility Event of Default, such Lender shall notify the Credit Facility Agent in writing of such Loan Facility Event of Default, which notice shall describe such Loan Facility Event of Default in reasonable detail (including the date of occurrence of the same), specifically refer to this Section 9.03(e) (Action Upon Event of Default) and indicate that such notice is a notice of default.

 

44


Section 9.04 Cash Collateralization of Letters of Credit. Subject to the Common Terms Agreement and the Common Security and Account Agreement:

(a) Amounts held in the LC Cash Collateral Account shall be the property of the Credit Facility Agent for the benefit of the Issuing Banks and Working Capital Lenders and shall be applied by the Credit Facility Agent to the repayment of LC Loans deemed made under any Letters of Credit.

(b) The balance, if any, in the LC Cash Collateral Account, after all Letters of Credit shall have expired or been fully drawn upon and giving effect to the payment of any LC Loans pursuant to Section 9.04(a), shall be applied to repay the other Loan Obligations according to Section 9.05 (Application of Proceeds).

Section 9.05 Application of Proceeds. Subject to the terms of the Intercreditor Agreement, any moneys received by the Credit Facility Agent from the Collateral Agent after the occurrence and during the continuance of a Loan Facility Event of Default and the period during which remedies have been initiated shall be applied in full or in part by the Credit Facility Agent against the Loan Obligations in accordance with Section 6.7(b) (Enforcement Proceeds Account) of the Common Security and Account Agreement (but without prejudice to the right of the Lenders or the Issuing Banks, subject to the terms of the Intercreditor Agreement, to recover any shortfall from the Borrower).

ARTICLE X

THE CREDIT FACILITY AGENT

Section 10.01 Appointment and Authority.

(a) Each of the Lenders and each of the Issuing Banks hereby appoints, designates and authorizes Natixis, New York Branch as its Credit Facility Agent under and for purposes of each Finance Document to which the Credit Facility Agent is a party, and in its capacity as the Credit Facility Agent, to act on its behalf as Senior Creditor Group Representative and the Designated Voting Party (as defined in the Intercreditor Agreement) for the Lenders and Issuing Banks. Natixis, New York Branch hereby accepts this appointment and agrees to act as the Credit Facility Agent for the Lenders and Issuing Banks in accordance with the terms of this Agreement. Each Lender and Issuing Bank hereby appoints and authorizes the Credit Facility Agent to execute and enter into each of the Common Terms Agreement, Intercreditor Agreement and Common Security and Account Agreement, and each other Finance Document to which it is party, on behalf of such Lender and such Issuing Bank, in its name, place and stead, to bind it to the representations, warranties, terms and conditions contained therein and to act on behalf of such Lender or such Issuing Bank under each Finance Document to which it is a party and in the absence of other written instructions from the Required Lenders received from time to time by the Credit Facility Agent (with respect to which the Credit Facility Agent agrees that it will comply, except as otherwise provided in this Section 10.01 or as otherwise advised by counsel, and subject in all cases to the terms of the Intercreditor Agreement), to exercise such powers hereunder and thereunder as are specifically delegated to or required of the Credit Facility Agent

 

45


by the terms hereof and thereof, together with such powers as may be reasonably incidental thereto. Where the Credit Facility Agent is required or permitted to act under this Agreement or under any other Finance Document, the Credit Facility Agent shall, notwithstanding anything herein or therein to the contrary, (i) be entitled to request instruction or direction in respect of any such rights, powers and discretions or clarification of any written instruction received by it, as to whether, and in what manner, it should exercise or refrain from exercising its rights, powers and discretions and (ii) unless the terms of the agreement unambiguously mandate the action, may refrain from acting (and will incur no liability in refraining to act) until that direction, instruction or clarification is received by it from the relevant parties or from a court of competent jurisdiction. Without limiting the generality of the foregoing sentence, the use of the term “agent” in this Agreement with reference to the Credit Facility Agent is not intended to connote any fiduciary or other implied (or express) obligations arising under agency doctrine of any applicable Government Rule. Instead, such term is used merely as a matter of market custom, and is intended to create or reflect only an administrative relationship between independent contracting parties.

(b) Except to the extent that the Credit Facility Agent is acting on express instructions, the Credit Facility Agent shall exercise such of the rights and powers vested in it by this Agreement, and use the same degree of care and skill in their exercise as a prudent Person would exercise or use under the circumstances in the conduct of his or her own affairs (taking into account the interests of all the Lenders and Issuing Banks benefiting from this Agreement). Nothing in this Agreement or any other Finance Document shall, in any case in which the Credit Facility Agent has failed to show such degree of care and skill, exempt the Credit Facility Agent from or indemnify it against any liability arising out of its own gross negligence, fraud or willful misconduct in relation to its duties under this Agreement or any other Finance Document as determined by a court of competent jurisdiction in a final non-appealable judgment.

(c) The Credit Facility Agent may not begin any legal action or proceeding in the name of a Lender or Issuing Bank, except as specifically permitted under the terms of this Agreement or the other Finance Documents.

(d) The provisions of this Article X are solely for the benefit of the Credit Facility Agent and the Term Lenders, and neither the Borrower nor any other Person shall have rights as a third party beneficiary of any of such provisions other than the Borrower’s rights under Section 10.07(a) and (b) (Resignation or Removal of Credit Facility Agent) and Section 10.13 (Agreement to Comply with Finance Documents).

Section 10.02 Rights as a Facility Lender or Hedging Bank. Each Person serving as the Credit Facility Agent hereunder or under any other Finance Document shall have the same rights and powers in its capacity as a Facility Lender or Hedging Bank, as the case may be, as any other Facility Lender or Hedging Bank, as the case may be, and may exercise the same as though it were not the Credit Facility Agent. Each such Person and its Affiliates may accept deposits from, lend money to, act as the financial advisor or in any other advisory capacity for and generally engage in any kind of business with the Borrower or Affiliates of the Borrower as if such Person were not the Credit Facility Agent hereunder and without any duty to account therefor to the Lenders and Issuing Banks.

 

46


Section 10.03 Exculpatory Provisions.

(a) The Credit Facility Agent shall not have any duties or obligations except those expressly set forth herein and in the other Finance Documents. Without limiting the generality of the foregoing, the Credit Facility Agent shall not:

(i) be subject to any fiduciary or other implied duties (except for an implied covenant of good faith), regardless of whether a Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing;

(ii) have any duty to take any discretionary action or exercise any discretionary powers, except discretionary rights and powers expressly contemplated hereby or by the other Finance Documents that the Credit Facility Agent is required to exercise as directed in writing by the Required Lenders (or such other number or percentage of the Lenders as shall be expressly provided for herein or in the other Finance Documents); provided that the Credit Facility Agent shall not be required to take any action that, in its opinion or the opinion of its counsel, may expose the Credit Facility Agent to liability or that is contrary to any Finance Document or applicable Government Rule; or

(iii) except as expressly set forth herein and in the other Finance Documents, have any duty to disclose, nor shall the Credit Facility Agent be liable for any failure to disclose, any information relating to the Borrower or any of its Affiliates that is communicated to or obtained by the Person serving as the Credit Facility Agent or any of its Affiliates in any capacity.

(b) The Credit Facility Agent shall not be liable for any action taken or not taken by it (i) with the prior written consent or at the request of the Required Lenders (or such other number or percentage of the Lenders or the Issuing Banks as may be necessary, or as the Credit Facility Agent may believe in good faith to be necessary, under the circumstances as provided in Section 11.01 (Decisions; Amendments, Etc.)) or (ii) in the absence of its own gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction by a final and non-appealable order. The Credit Facility Agent shall not be deemed to have knowledge or notice of the occurrence of any Loan Facility Event of Default unless the Credit Facility Agent has received a written notice in accordance with Section 9.03(d) (Action Upon Event of Default) or with Section 2.4(d) (Defaults) of the Intercreditor Agreement or from the Intercreditor Agent, the Obligors, the Pledgor or a Senior Creditor Group Representative referring to this Credit Facility Agreement, describing events or actions constituting a Loan Facility Event of Default and indicating that such notice is a notice of default. If the Credit Facility Agent receives such a notice of the occurrence of any Loan Facility Event of Default, the Credit Facility Agent shall give notice thereof to the Lenders, the Issuing Banks and the Intercreditor Agent. Subject to Article 16 (Common Remedies and Enforcement) of the Common Terms Agreement, the Credit Facility Agent shall take such action with respect to such Loan Facility Event of Default as is provided in Article IX (Default and Enforcement).

 

47


(c) The Credit Facility Agent shall not be responsible for or have any duty to ascertain or inquire into (i) any statement, warranty or representation made in or in connection with this Agreement or any other Finance Document, (ii) the contents of any certificate, report or other document delivered hereunder or thereunder or in connection herewith or therewith, (iii) the performance or observance of any of the covenants, agreements or other terms or conditions set forth herein or therein or the occurrence or Continuance of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default, (iv) the validity, enforceability, effectiveness or genuineness of this Agreement, any other Finance Document or any other agreement, instrument or document, or the perfection or priority of any Lien or security interest created or purported to be created by any Security Document, (v) the nature or sufficiency of any payment received by the Credit Facility Agent, or to present or file any claim or notice, or to take any action with respect to the Collateral or any part thereof or the moneys due or to become due in respect thereof or any property covered thereby, or (vi) the satisfaction of any condition set forth in Article VII (Conditions Precedent) or elsewhere herein, other than to confirm receipt of any items expressly required to be delivered to the Credit Facility Agent, except those irregularities or errors of which the Credit Facility Agent has actual knowledge, and provided that nothing herein shall constitute a waiver by any Obligor or any Lender or any Issuing Banks of any of their rights against the Credit Facility Agent as a result of its gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final non-appealable judgment. If any remittance or communication received by the Credit Facility Agent appears manifestly erroneous or irregular to the Credit Facility Agent, it shall be under a duty to make prompt inquiry to the Person originating such remittance or communication in order to determine whether a clerical error or inadvertent mistake has occurred.

(d) The Credit Facility Agent shall not be liable to the Obligors for any breach by any Lender or any Issuing Bank of this Agreement or any other Finance Document (other than by the Facility Agent’s own gross negligence, willful misconduct or fraud as determined by a court of competent jurisdiction in a final and nonappealable judgment) or be liable to any Lender or any Issuing Bank for any breach by any Obligor of this Agreement or any other Finance Document.

Section 10.04 Reliance by Credit Facility Agent.

(a) The Credit Facility Agent shall be entitled to rely upon, and shall not incur any liability for relying upon, any notice, request, certificate, consent, statement, instrument, document or other writing (including any electronic message, internet or intranet website posting or other distribution) believed by it to be genuine and to have been signed, sent or otherwise authenticated by the proper Person. The Credit Facility Agent also may rely upon any statement made to it orally or by telephone and believed by it to have been made by the proper Person, and shall not incur any liability for relying thereon. In determining compliance with any condition hereunder to the making of a Loan or issuance of a Letter of Credit that by its terms must be fulfilled to the satisfaction of each Lender, each Issuing Bank or the Required Lenders, the Credit Facility Agent may presume that such condition is satisfactory to such Lender, such Issuing Bank or the Required Lenders, as the case may be, unless the Credit Facility Agent has received notice

 

48


to the contrary from such Lender, such Issuing Bank or the Required Lenders or the Intercreditor Agent prior to the making of such Loan or issuance of such Letter of Credit. The Credit Facility Agent may consult with legal counsel, independent accountants and other experts selected by it, and shall not be liable for any action taken or not taken by it in accordance with the advice of any such counsel, accountants or experts. The Credit Facility Agent shall not be responsible for the negligence or misconduct of any legal counsel, independent accountants and other experts selected by it in good faith, and shall not be required to make any investigation as to the accuracy or sufficiency of any such advice or services; provided that nothing herein shall constitute a waiver by the Obligors, the Lenders or the Issuing Banks of any of their rights against (A) the Credit Facility Agent as a result of its gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final, non-appealable judgment or (B) such counsel, accountants or other experts.

(b) Each Obligor, each Lender and each Issuing Bank shall deliver to the Credit Facility Agent (or, in the case of the Obligors, deliver to the Intercreditor Agent for delivery to each Facility Agent) a list of authorized signatories, together, in the case of the Obligors, with a certificate of an officer of such party certifying the names and true signatures of such authorized signatories who are authorized to sign any notice, certificate, instrument, demand, request, direction, instruction, waiver, receipt, consent, agreement or other document or communication furnished to the Credit Facility Agent hereunder or under the other Finance Documents and the Credit Facility Agent shall be entitled to rely conclusively on such list until a new list is furnished by an Obligor, a Lender or an Issuing Bank, as the case may be, to the Credit Facility Agent (or, in the case of the Obligors, to the Intercreditor Agent for delivery to each Facility Agent).

Section 10.05 Delegation of Duties. The Credit Facility Agent may perform any and all of its duties and exercise any and all its rights and powers hereunder or under any other Finance Document by or through any one or more sub-agents appointed by the Credit Facility Agent. The Credit Facility Agent and any such sub-agent may perform any and all of its duties and exercise its rights and powers by or through their respective Related Parties. The exculpatory provisions of this Article X shall apply to any such sub-agent and to the Related Parties of the Credit Facility Agent, and shall apply to all of their respective activities in connection with their acting as or for the Credit Facility Agent.

Section 10.06 Indemnification by the Lenders. Without limiting the obligations of the Obligors hereunder or under the other Finance Documents, each Lender agrees that it shall, from time to time on demand by the Credit Facility Agent, indemnify the Credit Facility Agent and its Related Parties (ratably in accordance with its then applicable proportionate share) for any and all liabilities, obligations, losses, damages, penalties, actions, judgments, suits, costs, expenses (including reasonable legal fees) or disbursements of any kind or nature whatsoever, which may at any time be imposed on, incurred by or asserted against the Credit Facility Agent or any of its Related Parties in any way relating to or arising out of this Agreement, the other Finance Documents or any documents contemplated by or referred to herein or therein or the transactions contemplated hereby or thereby or the enforcement of any of the terms hereof or thereof or of any such other documents; provided, however, that no Lender shall be liable for any of the foregoing to the extent they arise solely from the Credit Facility Agent’s gross negligence, fraud or willful

 

49


misconduct as determined by a final non-appealable judgment of a court of competent jurisdiction. The Credit Facility Agent shall be fully justified in taking, refusing to take or continuing to take any action hereunder unless it shall first be indemnified to its satisfaction by the Lenders against any and all liability and expense which may be incurred by it by reason of taking, refusing to take or continuing to take any such action. Without limitation of the foregoing, each Lender agrees to reimburse, ratably in accordance with all its Loan Commitments, the Credit Facility Agent promptly upon demand for any out-of-pocket expenses (including counsel fees) incurred by the Credit Facility Agent in connection with the preparation, execution, administration, amendment, waiver, modification or enforcement of, or legal advice in respect of rights or responsibilities under, the Finance Documents, to the extent that the Credit Facility Agent is not reimbursed promptly for such expenses by the Obligors in accordance with the Finance Documents; provided that upon recovery of any or all of such costs and expenses by the Credit Facility Agent from the Obligors, the Credit Facility Agent shall remit to each Lender that has paid such costs and expenses to the Credit Facility Agent pursuant to this Section 10.06 (Indemnification by the Lenders) its ratable share of such amounts so recovered. The obligation of the Lenders to make payments pursuant to this Section 10.06 (Indemnification by the Lenders) is several and not joint or joint and several, and the same shall survive the payment in full of the Loan Obligations and the termination of this Agreement and the other Finance Documents.

Section 10.07 Resignation or Removal of Credit Facility Agent.

(a) The Credit Facility Agent may resign from the performance of all its functions and duties hereunder and under the other Finance Documents at any time by giving thirty (30) days’ prior notice to the Borrower, the Lenders and the Issuing Banks. The Credit Facility Agent may be removed at any time (i) by the Required Lenders for such Person’s gross negligence, fraud or willful misconduct or (ii) by the Borrower, with the consent of the Required Lenders and so long as no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing, for such Person’s gross negligence, fraud or willful misconduct. In the event Natixis, New York Branch is no longer the Credit Facility Agent, any successor Credit Facility Agent may be removed at any time with cause by the Required Lenders. Any such resignation or removal shall take effect upon the appointment of a successor Credit Facility Agent, in accordance with this Section 10.07 (Resignation or Removal of Credit Facility Agent) and Section 19.3 (Replacement of Facility Agents) of the Common Terms Agreement.

(b) Upon any notice of resignation by the Credit Facility Agent or upon the removal of the Credit Facility Agent by the Required Lenders, or by the Borrower with the approval of the Required Lenders pursuant to Section 10.07(a) (Resignation or Removal of Credit Facility Agent), the Required Lenders shall appoint a successor Credit Facility Agent, hereunder and under each other Finance Document to which the Credit Facility Agent is a party, such successor Credit Facility Agent to be a commercial bank or financial institution having combined capital and surplus of at least $1,000,000,000; provided that, if no Loan Facility Event of Default or Unmatured Loan Facility Event of Default shall then be Continuing, the appointment of a successor Credit Facility Agent shall also be subject to the prior written consent of the Borrower (such acceptance not to be unreasonably withheld, conditioned or delayed). The fees payable by the Borrower to a successor Credit Facility Agent shall be the same as those payable to its predecessor unless otherwise agreed between the Borrower and such successor.

 

50


(c) If no successor Credit Facility Agent shall have been so appointed and shall have accepted such appointment within sixty (60) days after (i) the retiring Credit Facility Agent gives notice of its resignation or (ii) the date fixed for such removal, as applicable, the Credit Facility Agent shall, at the expense of the Obligors, petition any court of competent jurisdiction in the United States for the appointment of a successor Credit Facility Agent. Such court may thereupon, after such notice, if any, as it may prescribe, appoint a successor Credit Facility Agent. If no successor Credit Facility Agent shall have been so appointed in accordance with clauses (a) and (b) above or (A) this clause (c) and shall have accepted such appointment within ninety (90) days or (B) in the case of this clause (c) if the Credit Facility Agent, acting reasonably, cannot determine a court of competent jurisdiction in the United States that will consider the petition contemplated in this clause (c) within sixty (60) days, in each case after (x) the retiring Credit Facility Agent gives notice of its resignation or (y) the date fixed for such removal, as applicable, the Credit Facility Agent may, at the expense of the Obligors, appoint a successor Credit Facility Agent meeting the criteria set forth in Section 10.07(b) (Resignation or Removal of Credit Facility Agent.); provided that, if no Loan Facility Event of Default shall then be Continuing, the appointment of such successor Credit Facility Agent shall also be subject to the prior written consent of the Borrower (such acceptance not to be unreasonably withheld, conditioned or delayed); provided, further, that if no successor Credit Facility Agent shall have been so appointed by the Credit Facility Agent within thirty (30) days after the termination of such 90-day period, the Obligors may appoint a successor Credit Facility Agent with the consent of the Required Lenders (such consent not to be unreasonably withheld or delayed).

(d) Upon the acceptance of a successor’s appointment as Credit Facility Agent hereunder and compliance with the provisions of Section 19.3 (Replacement of Facility Agents) of the Common Terms Agreement, such successor shall succeed to and become vested with all of the rights, powers, privileges and duties of the retiring (or removed) Credit Facility Agent, and the retiring (or removed) Credit Facility Agent shall be discharged from all of its duties and obligations hereunder or under the other Finance Documents. After the retirement or removal of the Credit Facility Agent hereunder and under the other Finance Documents, the provisions of this Article X and Section 11.07 (Indemnification by the Borrower) shall continue in effect for the benefit of such retiring (or removed) Person, its sub-agents and their respective Related Parties in respect of any actions taken or omitted to be taken by any of them while the retiring Person was acting in its capacity as Credit Facility Agent.

(e) Notwithstanding anything in this Agreement, no resignation or, as the case may be, removal of the Credit Facility Agent shall be effective until the following conditions are satisfied:

(i) the Credit Facility Agent has transferred to its successor all the rights and obligations in its capacity as Credit Facility Agent under this Credit Facility Agreement, the Common Terms Agreement and the other Finance Documents to which it is party as the Credit Facility Agent; and

 

51


(ii) the requirements of Section 19.3 (Replacement of Facility Agents) of the Common Terms Agreement have been satisfied.

Section 10.08 No Amendment to Duties of Credit Facility Agent Without Consent. The Credit Facility Agent shall not be bound by any waiver, amendment, supplement or modification of this Agreement or any other Finance Document that affects its rights or duties hereunder or thereunder unless such Credit Facility Agent shall have given its prior written consent, in its capacity as Credit Facility Agent thereto.

Section 10.09 Non-Reliance on Credit Facility Agent, Lenders and Issuing Banks. Each of the Lenders and Issuing Banks acknowledges that it has, independently and without reliance upon the Credit Facility Agent, any other Lender or Issuing Bank or any of their Related Parties and based on such documents and information as it has deemed appropriate, made its own credit analysis and decision to enter into this Agreement and make its extensions of credit. Each of the Lenders and Issuing Banks also acknowledges that it will, independently and without reliance upon the Credit Facility Agent or any other Lender or Issuing Bank or any of their Related Parties and based on such documents and information as it shall from time to time deem appropriate, continue to make its own decisions in taking or not taking action under or based upon this Agreement, any other Finance Document or any related agreement or any document furnished hereunder or thereunder.

Section 10.10 No Initial Coordinating Lead Arranger, Coordinating Lead Arranger or Documentation Bank Duties. Anything herein to the contrary notwithstanding, no Initial Coordinating Lead Arranger, Coordinating Lead Arranger or Documentation Bank shall have any powers, duties or responsibilities under this Agreement, except in its capacity, as applicable, as the Credit Facility Agent or Lender or Issuing Bank hereunder.

Section 10.11 Copies. The Credit Facility Agent shall give prompt notice to each Lender and each Issuing Bank of receipt of each notice or request required or permitted to be given to the Credit Facility Agent by the Obligors pursuant to the terms of this Agreement or any other Finance Document (unless concurrently delivered to the Lenders by such Obligor). The Credit Facility Agent will distribute to each Lender and each Issuing Bank each document or instrument (including each document or instrument delivered by the Obligors to the Credit Facility Agent pursuant to Article VI (Representations and Warranties), Article VII (Conditions Precedent) and Article VIII (Covenants)) received for the account of the Credit Facility Agent and copies of all other communications received by the Credit Facility Agent from the Obligors for distribution to the Lenders and the Issuing Banks by the Credit Facility Agent in accordance with the terms of this Agreement or any other Finance Document.

Section 10.12 General Provisions as to Payments.

(a) Subject to Section 4.16 (Pro Rata Treatment), the Credit Facility Agent promptly shall distribute to each Lender and each Issuing Bank its pro rata share of each payment of (a) principal and interest payable to the Lenders or Issuing Banks on the Loans, (b) fees hereunder received by the Credit Facility Agent for the account of the Lenders or the Issuing Banks and (c) any other Loan Obligations. The payments made for the account of each Lender and each

 

52


Issuing Bank shall be made and distributed to such Lender or Issuing Bank for the account of its facility office set forth in the Common Terms Agreement. Each Lender and each Issuing Bank shall have the right to alter its designated facility office upon written notice to the Credit Facility Agent, the Obligors and the Intercreditor Agent pursuant to Section 11.10 (Notices and Other Communications).

(b) Where a sum is to be paid to a Lender or Issuing Bank under the Finance Documents or another party to this Agreement by another party to this Agreement that is primarily liable for such sum, the Credit Facility Agent shall not be obliged to pay such sum to such other party (or to enter into or perform any related exchange contract) until it has established to its satisfaction that it has received such sum.

(c) If the Credit Facility Agent pays an amount to another party to this Agreement and it proves to be the case that the Credit Facility Agent had not actually received that amount for which another party to this Agreement is primarily liable, then the party to whom that amount (or the proceeds of any related exchange contract) was paid by the Credit Facility Agent shall on demand refund the same to the Credit Facility Agent together with interest on that amount from the date of payment to the date of receipt by the Credit Facility Agent, calculated by the Credit Facility Agent to reflect its cost of funds.

(d) The Credit Facility Agent acknowledges and agrees that, notwithstanding any provision to the contrary in any Finance Document, in no event shall the Lenders or Issuing Banks be obligated to pay any agency or other fee to the Credit Facility Agent even if the Obligors fail to do so.

Section 10.13 Agreement to Comply with Finance Documents. Each of the Lenders and Issuing Banks agrees for the benefit of the Borrower and each other that, in giving instructions to the Credit Facility Agent and the Intercreditor Agent and, where so permitted under this Agreement, the Intercreditor Agreement, Common Terms Agreement or the Common Security and Account Agreement, in taking Decisions by itself or through the Credit Facility Agent, including pursuing any Lender or Issuing Bank remedies against the Borrower, that such Lender or Issuing Bank shall act at all times in accordance with the terms of the Intercreditor Agreement, the Common Security and Account Agreement, the Common Terms Agreement, this Agreement and the applicable Finance Documents.

ARTICLE XI

MISCELLANEOUS PROVISIONS

Section 11.01 Decisions; Amendments, Etc.

(a) Subject to the terms of the Intercreditor Agreement and the Common Security and Account Agreement, no Modification or termination of any provision of this Agreement or other Decision by Lenders or Issuing Banks under this Agreement shall be effective unless in writing signed by the Obligors and Credit Facility Agent (acting on the instruction of the Required

 

53


Lenders), and each such Modification, termination or Decision shall be effective only in the specific instance and for the specific purpose for which given; provided that:

(i) the consent of each Lender or each Issuing Bank directly and adversely affected thereby will be required with respect to:

(A) increases in or extensions (other than pursuant to Section 2.09 (Incremental Commitments) or with respect to incurrence of any Additional Senior Debt to which such Lender has agreed to participate) of or change to the order of application of any reduction in any Commitments or change to the order of application of any prepayment of Loans from the application thereof set forth in the applicable provisions of Section 2.07 (Termination or Reduction of Commitments), Section 4.11 (Voluntary Prepayment), Section 4.12 (Mandatory Prepayment) (it being understood that a waiver of any of the conditions in Section 7.01 (Conditions to Closing), Section 7.02 (Conditions to Each Term Loan Advance) or Section 7.03 (Conditions to Each Working Capital Advance) or waiver of any Loan Facility Event of Default, Unmatured Loan Facility Event of Default or mandatory prepayment will not constitute an increase or extension of any Commitment);

(B) reductions of the principal of, or the interest or rate of interest specified herein on, any Loan, or any Fees or other amounts (including reduction in the amount to be paid in respect of any mandatory prepayments under Section 4.12 (Mandatory Prepayment)) payable to any Lender hereunder (other than by virtue of a waiver of any of the conditions in Section 7.01 (Conditions to Closing), Section 7.02 (Conditions to Each Term Loan Advance) or Section 7.03 (Conditions to Each Working Capital Advance), Loan Facility Event of Default or Unmatured Loan Facility Event of Default or change to a financial ratio);

(C) extensions of the Final Maturity Date or Working Capital Loan Termination Date under this Agreement, any date scheduled for any payment of principal, fees, interest or amortization payment (as applicable) under Section 4.01 (Repayment of Term Loan Advances), Section 4.04 (Interest Payment Dates) or Section 4.15 (Fees) or mandatory payment under Section 4.12 (Mandatory Prepayment) (it being understood that a waiver of any condition precedent or the waiver of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default or change to a financial ratio will not constitute an extension of the Final Maturity Date); and

(D) Modifications to the provisions of Section 4.16 (Pro Rata Treatment) or Section 4.17 (Sharing of Payments);

 

54


(ii) the consent of each Lender and each Issuing Bank will be required with respect to:

(A) changes to any provision of this Section 11.01, the definition of Required Lenders, or any other provision hereof specifying the number or percentage of Lenders or Issuing Banks required to amend, waive, terminate or otherwise modify any rights hereunder or make any determination or grant any consent hereunder;

(B) releases or Modifications of all or a material portion of the Collateral from the Lien of any of the Security Documents (other than as permitted in the Finance Documents);

(C) releases of all or a substantial portion of the value of the Guarantee by the Guarantor under or in connection with this Agreement, the Common Terms Agreement, the Common Security and Account Agreement or any Security Document (other than as permitted in the Finance Documents);

(D) assignment or transfer by any Obligor of any of its rights and obligations under this Agreement except with respect to any such assignment or transfer expressly permitted under this Agreement, the Common Terms Agreement or the Common Security and Account Agreement;

(E) any of the amendments contemplated in Schedule 1(a), (b), (c), (d), (e), (f), (g), (h) and (i) (All Loan Facilities Decisions) of the Intercreditor Agreement; provided, that the consent of all Lenders will be required with respect to Schedule 1(b) (All Loan Facilities Decisions) of the Intercreditor Agreement only to the extent such amendment adversely affects the timing or priority of payments for Senior Debt Obligations in the cash waterfall in Section 4.7 (Cash Waterfall) of the Common Security and Account Agreement; and

(F) satisfaction or waiver of each of the conditions in Section 7.01 (Conditions to Closing); and

(iii) the consent of any Lender (other than any Lender that is an Obligor, the Pledgor or the Sponsor or an Affiliate thereof except as set forth in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement) will be sufficient with respect to any Modification, termination or Decision specified in a Finance Document as being made solely by any individual Senior Creditor.

(b) Except as set forth in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, no Lender that is an Obligor or the Sponsor or an Affiliate thereof shall cast a vote with respect to any Decision.

(c) In the event that the Credit Facility Agent is required to cast a vote with respect to a Decision under this Agreement or under Section 3.6 (Other Voting Considerations) of the Intercreditor Agreement and in each other instance in which the Lenders or Issuing Banks are required to vote or make a Decision, a vote shall be taken among the Lenders or Issuing Banks in the timeframe reasonably specified by the Credit Facility Agent (which timeframe shall expire at least two (2) Business Days prior to the expiration of the time period specified in the notice provided by the Intercreditor Agent to the Credit Facility Agent pursuant to Section 4.5(a)(iii) (Certain Procedures Relating to Modifications, Instructions, and Exercises of Discretion) of the Intercreditor Agreement).

 

55


(d) No vote shall be required for any Decision or other action permitted to be taken by any individual Lender or any individual Issuing Bank pursuant to Section 9.03(b) (Action Upon Event of Default) of this Agreement, and the Credit Facility Agent shall be authorized to act at the direction of any Lender or any Issuing Bank in respect of any such Decision or action.

(e) Subject to clause (f) below, in the event any Lender or any Issuing Bank does not cast its votes by the later of (i) the timeframe specified by the Credit Facility Agent pursuant to clause (c) above and (ii) ten (10) Business Days following receipt of the request for such vote or Decision, the Borrower shall be entitled to instruct the Credit Facility Agent to deliver a notice to such Lender or Issuing Bank, informing it that if it does not respond within an additional five (5) Business Days of the date of such notice (or such longer period as the Borrower may reasonably determine in consultation with the Credit Facility Agent), its vote shall be disregarded. If such Lender or Issuing Bank (A) has not advised the Credit Facility Agent within the time specified in the additional notice whether it approves or disapproves of the applicable Decision or (B) has advised the Credit Facility Agent that it has determined to abstain from voting on such Decision, such Lender or Issuing Bank shall be deemed to have waived its right to consent, approve, waive or provide direction with respect to such Decision and shall be excluded from the numerator and denominator of such calculation for the purpose of determining whether the Required Lenders for the purpose of determining whether the Required Lenders have made a decision with respect to such action. Such Lender hereby waives any and all rights it may have to object to or seek relief from the decision of the Lenders voting with respect to such issue and agrees to be bound by such decision.

(f) The provisions of (c) and (e) above do not apply to any action that requires the consent of 100% of the Lenders or Issuing Banks or the consent of each affected Lender and Issuing Bank, as applicable, as set forth in Section 11.01(a)(i) and (ii) (Decisions; Amendments, Etc.) above.

(g) The agreements contemplated by this Section 11.01 (Decisions; Amendments, Etc.) shall not be required for any update to the Amortization Schedule delivered in accordance with Section 4.01(a) (Repayment of Term Loans) (which amendments shall be effective, absent any manifest error, upon delivery by the Credit Facility Agent to the Borrower and Intercreditor Agent of the updated Amortization Schedule in accordance with the provisions of that Section).

(h) With respect to any modification, consent or waiver under any Finance Document requiring the vote of the Credit Facility Agent as Senior Creditor Group Representative of the Lenders and the Issuing Banks, such vote will be cast in accordance with the Intercreditor Agreement.

(i) Notwithstanding anything herein, in the Common Terms Agreement or in the Common Security and Account Agreement to the contrary, the Lenders or Issuing Banks, or the Credit Facility Agent as Senior Credit Group Representative, shall not be entitled to vote on any covenant or event of default in the Common Terms Agreement if such covenant or event of default expressly does not extend to the Lenders or the Issuing Banks under the terms of this Agreement.

 

56


(j) Notwithstanding anything herein, each of the Lenders and Issuing Banks authorizes and instructs the Credit Facility Agent to make Administrative Decisions (as defined in the Intercreditor Agreement) with respect to the Credit Facility Agreement without the need for further authorization, consent or instruction from any Lender, Issuing Bank or other Credit Facility Secured Party with respect to such Administrative Decisions.

Section 11.02 Entire Agreement. This Agreement, the other Finance Documents and any agreement, document or instrument attached hereto or referred to herein integrate all the terms and conditions mentioned herein or incidental hereto and supersede all oral negotiations and prior writings in respect to the subject matter hereof.

Section 11.03 Applicable Government Rule; Jurisdiction; Etc.

(a) GOVERNING LAW. THIS AGREEMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK.

(b) SUBMISSION TO JURISDICTION. The provisions set forth in Section 23.14 (Consent to Jurisdiction) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

(c) Service of Process. Each party irrevocably consents to the service of any and all process in any such action or proceeding by the mailing of copies of such process to such Person at its then effective notice addresses pursuant to Section 11.10 (Notices and Other Communications).

(d) Immunity. The provisions set forth in Section 23.3 (Waiver of Immunity) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

(e) WAIVER OF JURY TRIAL. The provisions set forth in Section 23.13 (Waiver of Jury Trial) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

Section 11.04 Assignments.

(a) The provisions of this Agreement shall be binding upon and inure to the benefit of the parties hereto and their respective successors and assigns permitted hereby, except that none of the Obligors may assign or otherwise transfer any of its rights or obligations hereunder without the prior written consent of each of the Lenders, each of the Issuing Banks and the Credit Facility Agent (and any attempted assignment or other transfer by any Obligor without such consent shall be null and void), and no Lender or Issuing Bank may assign or otherwise transfer any of its rights or obligations hereunder except (i) to an Acceptable Lender in accordance with Section 11.04(b) and Section 11.04(i), (ii) by way of participation in accordance with Section 11.04(d) – (f) or (iii) by way of pledge or assignment of a security interest subject to the restrictions of Section 11.04(g) (and any other attempted assignment or transfer by any party hereto shall be null and void).

 

57


(b) (i) Subject to Section 11.04(i), Section 11.04(j) and this Section 11.04(b), any Lender may at any time after the date hereof assign to one or more Acceptable Lenders all or a portion of its rights and obligations under this Agreement (including all or a portion of its Commitments and the Loans at the time owing to it and, if such Loans are LC Loans, an equal portion of its Non-Fronting Limit); provided that, during the Availability Period for any Type of Loans or Commitments subject to assignment, (x) any such Acceptable Lender is an Eligible Assignee or has a then-current credit rating of at least equivalent to Baa2 from Moody’s or BBB from S&P or, if applicable, an insurer whose financial strength rating is at least equivalent to Baa1 from Moody’s or BBB+ from S&P or is otherwise creditworthy in the opinion of the Borrower (acting reasonably) in light of the Commitments proposed to be assigned, transferred or novated and (y) if the assigning Working Capital Lender is an Issuing Bank, the assignee is an Eligible Assignee or meets the ratings criteria within the definition of Issuing Bank; provided further that, on the date of such assignment, such assignment would not result in an increase in amounts payable by the Borrower under Section 5.03 (Increased Costs) or Section 5.05 (Funding Losses), unless such increase in amounts payable measured on such date of assignment is waived by the assigning and assuming Lenders.

(ii) Assignments made pursuant to this Section 11.04(b) shall be made with the prior written approval of the Borrower (such approval not to be unreasonably withheld or delayed and to be deemed to have been given by the Borrower if the Borrower has not responded in writing within fifteen (15) Business Days of request) unless (A) such assignment is to a Person described in clauses (a) or (b) of the definition of “Eligible Assignee” or (B) a Loan Facility Event of Default has occurred and is Continuing; provided, however, that where the prior written approval of the Borrower is not required, the assigning Existing Facility Lender shall promptly notify the Borrower of any such assignment, novation or transfer.

(iii) Except in the case of (A) an assignment of the entire remaining amount of the assigning Lender’s Commitment of a certain Type and, if such assignment is of a Working Capital Commitment, the Working Capital Loans and LC Loans owing to it and its entire Non-Fronting Limit or (B) an assignment to a Lender, or an Affiliate of a Lender, or an Approved Fund with respect to a Lender, the sum of (1) the outstanding Commitments, if any, and (2) the outstanding Loans subject to each such assignment (determined as of the date the Lender Assignment Agreement with respect to such assignment is delivered to the Credit Facility Agent or, if “Trade Date” is specified in the Lender Assignment Agreement, as of the Trade Date) shall not be less than $5,000,000, in the case of Term Loans and Term Loan Commitments, and $1,000,000 in the case of Working Capital Commitments and, with respect to the assignment of the Term Loans, in integral multiples of $1,000,000, and with respect to the assignment of Working Capital Loans, in integral multiples of $500,000, unless the Credit Facility Agent otherwise consents in writing.

 

58


(iv) Subject to Section 11.04(g) and Section 11.04(i), each partial assignment shall be made as an assignment of the same percentage of outstanding Commitments and outstanding Loans of the same Type and a proportionate part of all the assigning Lender’s rights and obligations under this Agreement with respect to the Loan and the Commitment of the such Type.

(v) The parties to each assignment shall execute and deliver to the Credit Facility Agent a Lender Assignment Agreement, in the form of Exhibit G (Form of Lender Assignment Agreement), together with a processing and recordation fee of $3,500; provided that (A) no such fee shall be payable in the case of an assignment to a Lender, an Affiliate of a Lender or an Approved Fund with respect to a Lender and (B) in the case of contemporaneous assignments by a Lender to one or more Approved Funds managed by the same investment advisor (which Approved Funds are not then Lenders hereunder), only a single such fee shall be payable for all such contemporaneous assignments.

(vi) If the Acceptable Lender is not a Lender prior to such assignment, it shall deliver to the Credit Facility Agent an administrative questionnaire and all documentation and other information required by bank regulatory authorities under applicable “know your customer” requirements.

(vii) In connection with any assignment of rights and obligations of any Defaulting Lender hereunder, no such assignment shall be effective unless and until, in addition to the other conditions thereto set forth herein, the parties to the assignment shall make such additional payments to the Credit Facility Agent in an aggregate amount sufficient, upon distribution thereof as appropriate (which may be outright payment, purchases by the assignee of participations or subparticipations, or other compensating actions, including funding, with the consent of the Borrower and the Credit Facility Agent, the applicable pro rata share of Loans previously requested but not funded by the Defaulting Lender, to each of which the applicable assignee and assignor hereby irrevocably consent), to (x) pay and satisfy in full all payment liabilities then owed by such Defaulting Lender to the Credit Facility Agent, and each other Lender hereunder (and interest accrued thereon), including any Issuing Bank pursuant to Section 3.02(e) (Reimbursement of Issuing Bank), and (y) acquire (and fund as appropriate) its full pro rata share of all Loans in accordance with its Commitment Percentage. Notwithstanding the foregoing, in the event that any assignment of rights and obligations of any Defaulting Lender hereunder shall become effective under applicable law without compliance with the provisions of this paragraph, then the assignee of such interest shall be deemed to be a Defaulting Lender for all purposes of this Agreement until such compliance occurs.

(viii) Subject to acceptance and recording thereof by the Credit Facility Agent pursuant to Section 11.04(c), from and after the effective date specified in each Lender Assignment Agreement, the Acceptable Lender thereunder shall be a party to this Agreement and, to the extent of the interest assigned by such Lender Assignment Agreement, have the rights and obligations of a Lender under this Agreement and the other applicable Finance Documents, and the assigning Lender thereunder shall, to the extent of the interest assigned by such Lender Assignment Agreement, be released from

 

59


its obligations under this Agreement and the other applicable Finance Documents (and, in the case of a Lender Assignment Agreement covering all of the assigning Lender’s rights and obligations under this Agreement, such Lender shall cease to be a party hereto or benefit from any Finance Document) but shall continue to be entitled to the benefits of Section 5.01 (LIBOR Lending UnlawfulIllegality), Section 5.03 (Increased Costs), Section 5.05 (Funding Losses), Section 5.06 (Taxes), Section 23.4 (Expenses) of the Common Terms Agreement and Section 12.18 (Other Indemnities) of the Common Security and Account Agreement with respect to facts and circumstances occurring prior to the effective date of such assignment; provided that except to the extent otherwise expressly agreed by the affected parties, no assignment by a Defaulting Lender will constitute a waiver or release of any claim of any party hereunder arising from that Lender’s having been a Defaulting Lender.

(ix) Upon request, the Borrower (at its expense) shall execute and deliver a Note to the assignee Lender and/or a revised Note to the assigning Lender reflecting such assignment.

(x) Any assignment or transfer by a Lender of rights or obligations under this Agreement that does not comply with this Section 11.04(b) shall be treated for purposes of this Agreement as a sale by such Lender of a participation in such rights and obligations in accordance with Section 11.04(d) through (f). Any assignment or transfer by an Issuing Bank of rights or obligations under this Agreement that does not comply with this Section 11.04(b) and Section 3.05 (Resignation as an Issuing Bank), as applicable, shall be null and void. Upon any such assignment, the Credit Facility Agent will deliver a notice thereof to the Borrower (provided that failure to deliver such notice shall not result in any liability for the Credit Facility Agent).

(xi) Any assignment of the Base Term Loan Commitment or the Contingency Reserve Term Loan Commitment shall be accompanied by a pro rata assignment of the Contingency Reserve Term Loan Commitment or the Base Term Loan Commitments, respectively.

(c) The Credit Facility Agent shall maintain the Register in accordance with Section 2.06(e) (Funding).

(d) Any Lender may at any time, without the consent of, or notice to, the Borrower or the Credit Facility Agent, sell participations to a Participant (other than a Disqualified Institution) in all or a portion of such Lender’s rights or obligations under this Agreement (including all or a portion of its Commitments or the Loans under this Agreement owing to it); provided that (i) such Lender’s obligations under this Agreement shall remain unchanged, (ii) such Lender shall remain solely responsible to the other parties hereto for the performance of such obligations and (iii) the Borrower, the Credit Facility Agent and the other Lenders shall continue to deal solely and directly with such Lender in connection with such Lender’s rights and obligations under this Agreement. For the avoidance of doubt, each Lender shall be responsible for the indemnity under Section 10.06 (Indemnification by the Lenders) with respect to any payments made by such Lender to its Participant(s).

 

60


(e) Any agreement or instrument pursuant to which a Lender sells such a participation shall provide that such Lender shall retain the sole right to enforce this Agreement and to approve any amendment, modification or waiver of any provision of this Agreement; provided that, such agreement or instrument may provide that such Lender will not, without the consent of the Participant, agree to any amendment, waiver or other modification described in the first proviso to Section 11.01 (Decisions; Amendments, Etc.) that directly affects such Participant. The Borrower agrees that each Participant shall be entitled to the benefits of Sections 5.03 (Increased Costs), 5.05 (Funding Losses) and 5.06 (Taxes) (subject to the requirements and limitations therein and in Article 21 (Tax Gross-Up and Indemnities) of the Common Terms Agreement, including the requirements under Section 21.5 (Status of Facility Lenders and Facility Agents) of the Common Terms Agreement (it being understood that any documentation required under Section 5.06 (Taxes) shall be delivered to the participating Lender)) to the same extent as if it were a Lender and had acquired its interest by assignment pursuant to paragraph (b) of this Section 11.04 (Assignments); provided that such Participant (A) agrees to be subject to the provisions of Section 5.04 (Obligation to Mitigate) as if it were an assignee under paragraph (b) of this Section 11.04; and (B) shall not be entitled to receive any greater payment under Sections 5.03 (Increased Costs) or 5.06 (Taxes), with respect to any participation, than its participating Lender would have been entitled to receive, except to the extent such entitlement to receive a greater payment results from a Change in Law that occurs after the Participant acquired the applicable participation.

(f) Each Lender that sells a participation agrees, at such Lender’s request and expense, to use reasonable efforts to cooperate with the Borrower to effectuate the provisions of Section 5.04 (Obligation to Mitigate) with respect to any Participant. To the extent permitted by law, each Participant also shall be entitled to the benefits of Section 11.13 (Right of Set-off) as though it were a Lender; provided that such Participant agrees to be subject to Section 4.17 (Sharing of Payments) as though it were a Lender. Each Lender that sells a participation shall, acting solely for this purpose as a non-fiduciary agent of the Borrower, maintain a Participant Register; provided that no Lender shall have any obligation to disclose all or any portion of the Participant Register (including the identity of any Participant or any information relating to a Participant’s interest in any commitments, loans or its other obligations under any Finance Document) to any Person except to the extent that such disclosure is necessary to establish that such commitment, loan or other obligation is in registered form under Section 5f.103-1(c) of the United States Treasury Regulations. The entries in the Participant Register shall be conclusive absent manifest error, and such Lender shall treat each Person whose name is recorded in the Participant Register as the owner of such participation for all purposes of this Agreement notwithstanding any notice to the contrary. For the avoidance of doubt, the Credit Facility Agent (in its capacity as Credit Facility Agent) shall have no responsibility for maintaining a Participant Register.

 

61


(g) Any Lender may at any time pledge or assign a security interest in all or any portion of its rights under this Agreement (including under its Notes, if any) to secure obligations of such Lender, including any pledge or assignment to secure obligations to a Federal Reserve Bank or any central bank having jurisdiction over such Lender in accordance with any applicable law, and this Section 11.04 (Assignments) shall not apply to any such pledge or assignment of a security interest; provided that no such pledge or assignment of a security interest shall release a Lender from any of its obligations hereunder or substitute any such pledgee or assignee for such Lender as a party hereto; provided, further that in no event shall the applicable Federal Reserve Bank, central bank, pledgee or trustee be considered to be a “Lender” or “Issuing Bank”, as applicable.

(h) The words “execution,” “signed,” “signature,” and words of like import in any Lender Assignment Agreement shall be deemed to include electronic signatures or the keeping of records in electronic form, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any applicable Government Rule, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

(i) All assignments by a Lender of all or a portion of its rights and obligations hereunder with respect to then outstanding Commitments of a certain Type shall be made only as an assignment of the same percentage of outstanding Commitments of such Type and outstanding Loans of such Type, and, in the case an assignment of rights and obligations with respect to a Working Capital Commitment, the Non-Fronting Limit under this Agreement held by such Lender. If a Working Capital Lender has no unused Working Capital Commitments, assignments of outstanding Loans owing to such Working Capital Lender may be made, together with a pro rata portion of such Working Capital Lender’s rights and obligations with respect to the Loans subject to such assignment, in such amounts, to such persons and on such terms as are permitted by and otherwise in accordance with Section 11.04(b).

(j) No sale, assignment, transfer, negotiation or other disposition of the interests of any Lender or Issuing Bank hereunder or under the other Finance Documents shall be allowed if it could reasonably be expected to require securities registration under any laws or regulations of any applicable jurisdiction.

(k) Notwithstanding anything to the contrary herein, (i) in no event may any Working Capital Lender assign all or any portion of its Working Capital Loans, Working Capital Commitments, LC Loans or participations in Letters of Credit to an Affiliated Lender and (ii) subject to Section 11.04(b) (Assignments) and so long as no Loan Facility Event of Default has occurred and is Continuing, any Term Lender may assign all or any portion of its Term Loans and/or Term Loan Commitments hereunder to any Affiliated Lender (pursuant to an assignment agreement in which such Affiliated Lender shall identify itself), but only if after giving effect to such assignment, Affiliated Lenders shall not, in the aggregate, own or hold Term Loans and Term Loan Commitments with an aggregate principal amount in excess of 25% of the aggregate principal amount of the Term Loans then outstanding and the remaining Term Loan Commitments (calculated as of the date of such purchase) (the “Affiliated Lender Cap”); provided that, to the extent that any assignment to any Affiliated Lender would result in the aggregate principal amount of Term Loans and Term Loan Commitments held by Affiliated

 

62


Lenders exceeding the Affiliated Lender Cap (after giving effect to any substantially simultaneous cancellation thereof), the assignment of such excess amount shall be null and void. To the extent that any Affiliated Lender holds Term Loans or Term Loan Commitments, no such Affiliated Lender shall (i) except as set forth in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, (A) have any voting or approval rights under the Finance Documents or (B) be permitted to require the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Senior Creditor to undertake any action (or refrain from taking any action) pursuant to or with respect to the Finance Documents, (ii) be permitted to, in its capacity as a Lender, attend any meeting or conference call with the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Senior Creditor unless the Borrower has been invited to attend such conference calls or meetings, receive any information from the Administrative Agent, the Collateral Agent, the Intercreditor Agent, any Lender or any other Senior Creditor unless such information has been made available to the Borrower (other than the right to receive notices of borrowings, notices of prepayments, and other administrative notices in respect of its Term Loans or Term Loan Commitments required to be delivered pursuant to Article II (Commitments and Advances) or Article IV (Repayments, Prepayments, Interest and Fees)) or have any rights of inspection or access relating to any Collateral Party or (iii) be permitted to make or bring any claim, in its capacity as Lender, against the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Lender or Senior Creditor with respect to the duties and obligations of such Person under the Finance Documents other than in the case of a material breach by the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Lender or Senior Creditor to such Affiliated Lender (except with respect to any such breaches applicable to the Lenders generally unless the other Lenders have made or brought such claims).

(l) Each Affiliated Lender, solely in its capacity as a Lender, hereby agrees, that, if any Collateral Party or any of their assets shall be subject to any voluntary or involuntary proceeding commenced under the Bankruptcy Code (“Bankruptcy Proceedings”), (i) such Affiliated Lender, solely in its capacity as a Lender, shall not take any step or action in such Bankruptcy Proceeding to object to, impede, or delay the exercise of any right or the taking of any action by the Credit Facility Agent (or the taking of any action by a third party that is supported by the Administrative Agent) in relation to such Affiliated Lender’s claim with respect to its Term Loans or Term Commitments (an “Affiliated Lender Claim”) (including, without limitation, objecting to any debtor in possession financing, use of cash collateral, grant of adequate protection, sale or disposition, compromise, or plan of reorganization) so long as such Affiliated Lender is treated in connection with such exercise or action on the same or better terms as the other Lenders and (ii) with respect to any matter requiring the vote of Lenders during the pendency of a Bankruptcy Proceeding (including voting on any plan of reorganization), (A) the Advances held by such Affiliated Lender (and any Affiliated Lender Claim with respect thereto) shall be deemed to be voted in such Bankruptcy Proceeding in the same proportion as the allocation of voting with respect to such matter by those Lenders who are not Affiliated Lenders, so long as such Affiliated Lender is treated in connection with the exercise of such right or taking of such action on the same or better terms as the other Lenders and (B) the Affiliated Lenders shall agree that the Credit Facility Agent shall vote on behalf of such Affiliated Lenders. For the avoidance of doubt, the Lenders and each Affiliated Lender, solely in its capacity as a Lender, agrees and acknowledge that the provisions set forth in this Section 11.04(l) constitute a “subordination agreement” as such term is contemplated by, and utilized in, Section 510(a) of the Bankruptcy Code, and, as such, would be enforceable for all purposes in any case where a Collateral Party has filed for protection under the Bankruptcy Code.

 

63


Section 11.05 Benefits of Agreement. Nothing in this Agreement or any other Finance Document, express or implied, shall be construed to give to any Person, other than the parties hereto, the Initial Coordinating Lead Arrangers, the Coordinating Lead Arranger, the Documentation Banks and each of their successors and permitted assigns under this Agreement or any other Finance Document, Participants to the extent provided in Section 11.04 (Assignments) and, to the extent expressly contemplated hereby, the Related Parties of each of the Credit Facility Agent, the Collateral Agent, the Lenders and the Issuing Banks, any benefit or any legal or equitable right or remedy under this Agreement.

Section 11.06 Counterparts; Effectiveness. This Agreement may be executed in counterparts (and by different parties hereto in different counterparts), each of which shall constitute an original, but all of which when taken together shall constitute a single contract. This Agreement shall become effective when it has been executed by the Credit Facility Agent and when the Credit Facility Agent has received counterparts hereof that, when taken together, bear the signatures of each of the other parties hereto. Delivery of an executed counterpart of a signature page of this Agreement by portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Agreement.

Section 11.07 Indemnification by the Borrower.

(a) The Obligors hereby agree to indemnify the Credit Facility Agent, each Lender, each Issuing Bank, each Initial Coordinating Lead Arranger, the Coordinating Lead Arranger, each Documentation Bank and each Related Party of any of the foregoing Persons in accordance with Section 12.18 (Other Indemnities) of the Common Security and Account Agreement and Section 2.15 (Other Indemnities) of the Intercreditor Agreement, which shall be applied mutatis mutandis to the indemnified parties under this Agreement, as well as with respect to reliance by such indemnified party on each notice purportedly given by or on behalf of the Borrower pursuant to Section 11.10 (Notices and Other Communications).

(b) To the extent that any Obligor for any reason fails to pay any amount required under Section 12.18 (Other Indemnities) of the Common Security and Account Agreement or clause (a) above to be paid by it to any of the Credit Facility Agent, any sub-agent thereof or any Related Party of any of the foregoing, each Lender severally agrees to pay to the Credit Facility Agent, any such sub-agent, or such Related Party, as the case may be, such Lender’s ratable share (determined as of the time that the applicable unreimbursed expense or indemnity payment is sought) of such unpaid amount; provided that, the unreimbursed expense or indemnified loss, claim, damage, liability or related expense, as the case may be, was incurred by or asserted against the Credit Facility Agent or any sub-agent thereof in its capacity as such, or against any Related Party of any of the foregoing acting for the Credit Facility Agent or any sub-agent thereof in connection with such capacity. The obligations of the Lenders under this Section 11.07(b) (Indemnification by the Borrower) are subject to the provisions of Section 2.06

 

64


(Funding). The obligations of the Lenders to make payments pursuant to this Section 11.07(b) (Indemnification by the Borrower) are several and not joint and shall survive the payment in full of the Loan Obligations and the termination of this Agreement. The failure of any Lender to make payments on any date required hereunder shall not relieve any other Lender of its corresponding obligation to do so on such date, and no Lender shall be responsible for the failure of any other Lender to do so.

(c) The provisions of this Section 11.07 (Indemnification by the Borrower) shall not supersede Sections 5.03 (Increased Costs) and 5.06 (Taxes).

Section 11.08 Interest Rate Limitation. Notwithstanding anything to the contrary contained in any Finance Document, the interest paid or agreed to be paid under the Finance Documents shall not exceed the maximum rate of non-usurious interest permitted by applicable Government Rule (the “Maximum Rate”). If the Credit Facility Agent or any Lender or any Issuing Bank shall receive interest in an amount that exceeds the Maximum Rate, the excess interest shall be applied to the principal of the Loans or, if it exceeds such unpaid principal, refunded to the Borrower. In determining whether the interest contracted for, charged, or received by the Credit Facility Agent or any Lender or Issuing Bank exceeds the Maximum Rate, such Person may, to the extent permitted by applicable Government Rule, (a) characterize any payment that is not principal as an expense, fee, or premium rather than interest, (b) exclude prepayments and the effects thereof, and (c) amortize, prorate, allocate, and spread in equal or unequal parts the total amount of interest throughout the contemplated term of the Loan obligations hereunder.

Section 11.09 No Waiver; Cumulative Remedies. No failure by any Credit Facility Secured Party to exercise, and no delay by any such Person in exercising, any right, remedy, power or privilege hereunder or under any other Finance Document shall operate as a waiver thereof; nor shall any single or partial exercise of any right, remedy, power or privilege hereunder preclude any other or further exercise thereof or the exercise of any other right, remedy, power or privilege. The rights, remedies, powers and privileges herein provided, and provided under each other Finance Document, are cumulative and not exclusive of any rights, remedies, powers and privileges provided by law.

Section 11.10 Notices and Other Communications.

(a) Any communication between the parties hereto or notices provided herein to be given may be given as provided in Section 23.8 (Notices) of the Common Terms Agreement, which shall apply mutatis mutandis to this Section 11.10 (Notices and Other Communications) as if fully set forth herein except that references to the Intercreditor Agent shall be deemed references to the Credit Facility Agent as the context requires.

(b) The Credit Facility Agent, the Issuing Banks, the Collateral Agent and the Lenders shall be entitled to rely and act upon any written notices purportedly given by or on behalf of the Borrower even if (i) such notices were not made in a manner specified herein, were incomplete or were not preceded or followed by any other form of notice specified herein, or (ii) the terms thereof, as understood by the recipient, varied from any confirmation thereof. All telephonic notices to and other telephonic communications with the Credit Facility Agent, the Collateral Agent, the Issuing Banks and the Lenders by the Borrower may be recorded by the Credit Facility Agent, the Collateral Agent, the Issuing Banks and the Lenders, as applicable, and each of the parties hereto hereby consents to such recording.

 

65


(c) Notwithstanding the above, nothing herein shall prejudice the right of the Credit Facility Agent, the Collateral Agent, any of the Issuing Banks and any of the Lenders to give any notice or other communication pursuant to any Finance Document in any other manner specified in such Finance Document.

(d) Notwithstanding anything to the contrary in any other Finance Document, for so long as Natixis, New York Branch is the Credit Facility Agent, the Borrower hereby agrees that it will provide to the Credit Facility Agent all information, documents and other materials that it is obligated to furnish to the Credit Facility Agent pursuant to the Finance Documents, including all notices, requests, financial statements, financial and other reports, certificates and other information materials, but excluding any such communication that (i) relates to any Advance, (ii) relates to the payment of any principal or other amount due under this Agreement prior to the scheduled date therefor, (iii) provides notice of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default or (iv) is required to be delivered to satisfy any condition precedent to any Advance (all such non-excluded communications being referred to herein collectively as “Communications”), in an electronic/soft medium in a format acceptable to the Credit Facility Agent at the email addresses specified in Schedule Q – 2 (Addresses for Notices to Facility Agents and Facility Lenders) of the Common Terms Agreement. In addition, the Borrower agrees to continue to provide the Communications to the Credit Facility Agent in the manner specified in the Finance Documents but only to the extent requested by the Credit Facility Agent.

Section 11.11 USA Patriot Act Notice. Each of the Lenders, the Credit Facility Agent, the Collateral Agent and the Issuing Banks hereby notifies the Borrower that pursuant to the requirements of the USA Patriot Act, it is required to obtain, verify and record information that identifies the Borrower, the Guarantor and the Pledgor, which information includes the name and address of the Borrower and other information that will allow such Lender, the Credit Facility Agent, the Collateral Agent or such Issuing Bank, as applicable, to identify the Borrower, the Guarantor and the Pledgor in accordance with the USA Patriot Act.

Section 11.12 Payments Set Aside. To the extent that any payment by or on behalf of the Borrower is made to the Credit Facility Agent, the Collateral Agent, any Issuing Bank or any Lender, or the Credit Facility Agent, the Collateral Agent, any Issuing Bank or any Lender (as the case may be) exercises its right of setoff, and such payment or the proceeds of such setoff or any part thereof is subsequently invalidated, declared to be fraudulent or preferential, set aside or required (including pursuant to any settlement entered into by the Credit Facility Agent, the Collateral Agent, any Issuing Bank or such Lender in its discretion) to be repaid to a trustee, receiver or any other party, in connection with any Bankruptcy Proceeding or otherwise, then (a) to the extent of such recovery, the Loan Obligation or part thereof originally intended to be satisfied by such payment shall be revived and continued in full force and effect as if such payment had not been made or such setoff had not occurred, and (b) each Lender and each

 

66


Issuing Bank severally agrees to pay to the Credit Facility Agent or the Collateral Agent upon demand its applicable share (without duplication) of any amount so recovered from or repaid by the Credit Facility Agent or the Collateral Agent, as the case may be, plus interest thereon from the date of such demand to the date such payment is made at a rate per annum equal to the Federal Funds Effective Rate from time to time in effect. The obligations of the Lenders and the Issuing Banks under this Section 11.12 (Payments Set Aside) shall survive the payment in full of the Loan Obligations and the termination of this Agreement.

Section 11.13 Right of Set-Off. The provisions set forth in Section 23.2 (Right of Set-Off) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

Section 11.14 Severability. If any provision of this Agreement or any other Finance Document is held to be illegal, invalid or unenforceable, (a) the legality, validity and enforceability of the remaining provisions of this Agreement and the other Finance Documents shall not be affected or impaired thereby and (b) the parties shall endeavor in good faith negotiations to replace the illegal, invalid or unenforceable provisions with valid provisions the economic effect of which comes as close as possible to that of the illegal, invalid or unenforceable provisions. The invalidity of a provision in a particular jurisdiction shall not invalidate or render unenforceable such provision in any other jurisdiction.

Section 11.15 Survival. Notwithstanding anything in this Agreement to the contrary, Section 5.01 (LIBOR Lending UnlawfulIllegality), Section 5.03 (Increased Costs), Section 5.05 (Funding Losses), Section 5.06 (Taxes), Section 10.06 (Indemnification by the Lenders), Section 11.07 (Indemnification by the Borrower), Section 11.12 (Payments Set Aside) and Section 11.20 (No Recourse) shall survive any termination of this Agreement. In addition, each representation and warranty made hereunder and in any other Finance Document or other document delivered pursuant hereto or thereto or in connection herewith or therewith shall survive the execution and delivery hereof and thereof. Such representations and warranties shall be considered to have been relied upon by the Credit Facility Secured Parties regardless of any investigation made by any Credit Facility Secured Party or on their behalf and notwithstanding that the Credit Facility Secured Parties may have had notice or knowledge of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default at the time of any Advance or Loan hereunder, and shall continue in full force and effect as of the date made or any date referred to herein as long as any Loan or any other Senior Debt Obligation hereunder or under any other Finance Document shall remain unpaid or unsatisfied.

Section 11.16 Treatment of Certain Information; Confidentiality. The Credit Facility Agent, the Collateral Agent, and each of the Lenders and Issuing Banks agrees to maintain the confidentiality of the Confidential Information and all information disclosed to it concerning this Agreement and the other Finance Documents in accordance with Section 23.7 (Confidentiality) of the Common Terms Agreement.

 

67


Section 11.17 Waiver of Consequential Damages, Etc.

(a) The provisions set forth in Section 23.18 (Limitations on Liability) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

(b) No party hereto or its Related Parties shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Finance Documents or the transactions contemplated hereby or thereby.

Section 11.18 Waiver of Litigation Payments. To the extent that any party hereto may, in any action, suit or proceeding brought in any of the courts referred to in Section 11.03(b) (Applicable Government Rule; Jurisdiction, Etc.) or elsewhere arising out of or in connection with this Agreement or any other Finance Document to which it is a party, be entitled to the benefit of any provision of law requiring any other party hereto in such action, suit or proceeding to post security for the costs of such Person or to post a bond or to take similar action, each such Person hereby irrevocably waives such benefit, in each case to the fullest extent now or in the future permitted under the laws of the State of New York or, as the case may be, the jurisdiction in which such court is located.

Section 11.19 Reinstatement. This Agreement shall continue to be effective or be reinstated, as the case may be, if (and only to the extent that) any payment or performance of the obligations of the Borrower hereunder is rescinded, avoided, voidable, liable to be set aside, reduced or otherwise not properly payable to, or must otherwise be returned or restored by the Credit Facility Agent or any Lender or any Issuing Bank as a result of (i) Bankruptcy, insolvency, reorganization with respect to the Borrower or the Credit Facility Agent or any Lender or any Issuing Bank, (ii) upon the dissolution of, or appointment of any intervenor, conservator, trustee or similar official for the Borrower, the Credit Facility Agent or any Lender or any Issuing Bank or for any substantial part of the Borrower’s or any other such Person’s assets, (iii) as a result of any settlement or compromise with any Person (including the Borrower) in respect of such payment or otherwise, or (iv) any similar event or otherwise and, in such case, the provisions of Section 10.1 (Nature of Obligations) of the Common Security and Account Agreement, which shall apply hereto mutatis mutandis.

Section 11.20 No Recourse. The provisions set forth in Section 10.3 (Limitation on Recourse) of the Common Security and Account Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

Section 11.21 Intercreditor Agreement. Any actions, consents, approvals, authorizations or discretion taken, given, made or exercised, or not taken, given, made or exercised by the Credit Facility Agent, acting as a Senior Creditor Group Representative on behalf of the Lenders and Issuing Banks, in accordance with the Intercreditor Agreement shall be binding on each Lender and Issuing Bank. Notwithstanding anything to the contrary herein, in the case of any inconsistency between this Agreement and the Intercreditor Agreement, the Intercreditor Agreement shall govern.

 

68


Section 11.22 Termination. This Agreement shall terminate and shall have no force and effect (except with respect to the provisions that expressly survive termination of this Agreement) in accordance with the provisions of Section 23.1 (Termination) of the Common Terms Agreement and if the Discharge Date with respect to the Loan Obligations has occurred.

Section 11.23 Acknowledgment and Consent to Bail-In of EEA Financial Institutions.

(a) Notwithstanding anything to the contrary in any Finance Document, each party hereto acknowledges that any liability of any Lender or Issuing Bank that is an EEA Financial Institution arising under any Finance Document, to the extent such liability is unsecured, may be subject to the Write-Down and Conversion Powers of an EEA Resolution Authority and agrees and consents to, and acknowledges and agrees to be bound by:

(i) the application of any Write-Down and Conversion Powers by an EEA Resolution Authority to any such liabilities arising hereunder which may be payable to it by any Lender or Issuing Bank that is an EEA Financial Institution; and

(ii) the effects of any Bail-in Action on any such liability, including, if applicable:

(A) a reduction in full or in part or cancellation of any such liability;

(B) a conversion of all, or a portion of, such liability into shares or other instruments of ownership in such EEA Financial Institution, its parent undertaking, or a bridge institution that may be issued to it or otherwise conferred on it, and that such shares or other instruments of ownership will be accepted by it in lieu of any rights with respect to any such liability under this Agreement or any other Finance Document; or

(b) the variation of the terms of such liability in connection with the exercise of the Write-Down and Conversion Powers of any EEA Resolution Authority.

[Remainder of page intentionally blank. Next page is signature page.]

 

69


IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by their respective officers as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as Borrower

By:

Name:

Title:

[Signature Page to Credit Facility Agreement]


TRANSCAMERON PIPELINE, LLC,

as Guarantor

By:

Name:

Title:

[Signature Page to Credit Facility Agreement]


Solely for purposes of Section 3.06 of the Credit Facility Agreement:

MIZUHO BANK (USA),

as Collateral Agent

By:
Name:
Title:

[Signature Page to Credit Facility Agreement]


NATIXIS, NEW YORK BRANCH,
as Credit Facility Agent
By:
Name:
Title:
By:
Name:
Title:

[Signature Page to Credit Facility Agreement]


[•],

as Term Lender

By:

Name:

Title:

 

[Signature Page to Credit Facility Agreement]


[ • ],

as Working Capital Lender

By:

Name:

Title:

 

[Signature Page to Credit Facility Agreement]


[ • ],

as Issuing Bank

By:

Name:

Title:

 

[Signature Page to Credit Facility Agreement]


EXHIBIT A TO

CREDIT FACILITY AGREEMENT

Definitions

Adjusted Term SOFR” means the rate per annum equal to (a) Term SOFR for the applicable calculation plus (b) the Term SOFR Adjustment.

Advance” means, as context requires, a Term Loan Advance, a Working Capital Advance, or both.

Advance Date” means, with respect to each Advance, the date on which funds are disbursed by the Lenders (or the Credit Facility Agent on their behalf) to the Borrower.

Affiliated Lender” means Sponsor or any of its Affiliates.

Affiliated Lender Cap” has the meaning specified in Section 11.04(k) (Assignments).

Affiliated Lender Claim” has the meaning specified in Section 11.04(l) (Assignments).

Aggregate Commitments” means, as context requires, the sum of the Term Loan Commitments or the sum of the Working Capital Commitments.

Aggregate Term Loan Commitments” means the sum of the Term Loan Commitments.

Aggregate Working Capital Commitments” means the sum of the Working Capital Commitments.

Agreement” has the meaning provided in the preamble.

Amortization Schedule” means the amortization schedule set forth in Schedule III.

Applicable Margin” means (a) with respect to Loans that are LIBORSOFR Loans, (i) from the Closing Date until the third (3rd) anniversary of the Closing Date, 2.375% per annum, (ii) from the third (3rd) anniversary of the Closing Date until the fifth (5th) anniversary of the Closing Date, 2.625% per annum, and (iii) from the fifth (5th) anniversary of the Closing Date until the Final Maturity Date, 2.875% per annum, and (b) with respect to Loans that are Base Rate Loans, (i) from the Closing Date until the third (3rd) anniversary of the Closing Date, 1.375% per annum, (ii) from the third (3rd) anniversary of the Closing Date until the fifth (5th) anniversary of the Closing Date, 1.625% per annum, and (iii) from the fifth (5th) anniversary of the Closing Date until the Maturity Date, 1.875% per annum.

Availability Period” means, as context requires, the Term Loan Availability Period or the Working Capital Availability Period.

 

A-1


Available Tenor” means, as of any date of determination and with respect to the then-current Benchmark, as applicable, (a) if such Benchmark is a term rate, any tenor for such Benchmark (or component thereof) that is or may be used for determining the length of an interest period pursuant to this Agreement or (b) otherwise, any payment period for interest calculated with reference to such Benchmark (or component thereof) that is or may be used for determining any frequency of making payments of interest calculated with reference to such Benchmark pursuant to this Agreement, in each case, as of such date and not including, for the avoidance of doubt, any tenor for such Benchmark that is then-removed from the definition of “Interest Period” pursuant to Section 5.07(d) (Replacement Benchmark Setting—Unavailability of Tenor of Benchmark).

Bankruptcy Proceeding” has the meaning set forth in Section 11.04(l) (Assignments).

Base Rate” means, for any day, a fluctuating rate per annum equal to the highest of (a) the Federal Funds Effective Rate plus 0.50%, (b) the prime rate published in The Wall Street Journal for such day; provided that if The Wall Street Journal ceases to publish for any reason such rate of interest, “Base Rate” shall mean the prime lending rate as set forth on the Bloomberg page PRIMBB Index (or successor page) for such day (or such other service as determined by the Credit Facility Agent from time to time for purposes of providing quotations of prime lending interest rates) and (c) the LIBORAdjusted Term SOFR for an interest period of one month plus 1.00%; provided that, for purposes of this Agreement, if the Base Rate for any interest period is less than zero percent (0%), it shall be deemed zero percent (0%) for such interest period.

Base Rate Loan” means any Term Loan bearing interest at a rate determined by reference to the Base Rate and the provisions of Article IIIII (Commitments and Advance) and Article IV (Repayments, Prepayments, Interest and Fees).

Base Rate Term SOFR Determination Day” has the meaning provided in the definition of “Term SOFR.”

Base Term Loan Commitment” means the commitment of a Term Lender to make or otherwise fund a Term Loan pursuant to Section 2.01(a)(i) (Term Loans), as set forth opposite the name of such Term Lender in the column entitled “Base Term Loan Commitment” in Schedule I (Lenders, Commitment) or if such Term Lender has entered into one or more Lender Assignment Agreements, set forth opposite the name of such Term Lender and any assignor Term Lender in the Register maintained by the Credit Facility Agent pursuant to Section 2.06(f) (Funding), as the same may be reduced in accordance with Section 2.07 (Termination or Reduction of Commitments), and “Base Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

“Benchmark” means, initially, the Term SOFR Reference Rate; provided that, if a Benchmark Transition Event has occurred with respect to the Term SOFR Reference Rate or the then-current Benchmark, then “Benchmark” means the applicable Benchmark Replacement to the extent that such Benchmark Replacement has replaced such prior benchmark rate pursuant to Section 5.07(a) (Replacement Benchmark Setting – Benchmark Replacement).

 

A-2


Benchmark Replacement” means, with respect to any Benchmark Transition Event, the sum of: (a) the alternate benchmark rate (which may include Term SOFR) that has been selected by the Credit Facility Agent and the Borrower giving due consideration to (i) any selection or recommendation of a replacement benchmark rate or the mechanism for determining such a rate by the Relevant Governmental Body or (ii) any evolving or then-prevailing market convention for determining a benchmark rate of interest as a replacement to LIBOR for U.S. dollar-denominatedthe then-current Benchmark for Dollar-denominated syndicated credit facilities at such time and (b) the related Benchmark Replacement Adjustment; provided that, if thesuch Benchmark Replacement as so determined would be less than zero, thesuch Benchmark Replacement will be deemed to be zero for the purposes of this Agreement and other applicable Finance Documents.

Benchmark Replacement Adjustment” means, with respect to any replacement of LIBORthe then-current Benchmark with an Unadjusted Benchmark Replacement for each applicable Interest Period, the spread adjustment, or method for calculating or determining such spread adjustment, (which may be a positive or negative value or zero) that has been selected by the Credit Facility Agent and the Borrower giving due consideration to (i) any selection or recommendation of a spread adjustment, or method for calculating or determining such spread adjustment, for the replacement of LIBORsuch Benchmark with the applicable Unadjusted Benchmark Replacement by the Relevant Governmental Body or (ii) any evolving or then-prevailing market convention for determining a spread adjustment, or method for calculating or determining such spread adjustment, for the replacement of LIBORsuch Benchmark with the applicable Unadjusted Benchmark Replacement for U.S. dollar-denominatedDollar-denominated syndicated credit facilities at such time.

Benchmark Replacement Conforming Changes” means, with respect to any Benchmark Replacement, any technical, administrative or operational changes (including changes to the definition of “Base Rate,” the definition of “Interest Period,” timing and frequency of determining rates and making payments of interest and other administrative matters) that the Credit Facility Agent decides, with the consent of the Borrower (not to be unreasonably withheld, conditioned or delayed), may be appropriate to reflect the adoption and implementation of such Benchmark Replacement and to permit the administration thereof by the Credit Facility Agent in a manner substantially consistent with market practice (or, if the Credit Facility Agent decides that adoption of any portion of such market practice is not administratively feasible or if the Credit Facility Agent determines that no market practice for the administration of the Benchmark Replacement exists, in such other manner of administration as the Credit Facility Agent decides, with the consent of the Borrower (not to be unreasonably withheld, conditioned or delayed), is reasonably necessary in connection with the administration of this Agreement).

Benchmark Replacement Date” means the earlierearliest to occur of the following events with respect to LIBORthe then-current Benchmark:

(1a) in the case of clause (1a) or (2b) of the definition of “Benchmark Transition Event,” the later of (ai) the date of the public statement or publication of information referenced therein and (bii ) the date on which the administrator of LIBORsuch Benchmark (or the published component used in the calculation thereof) permanently or indefinitely ceases to provide LIBORall Available Tenors of such Benchmark (or such component thereof); or

 

A-3


(2b) in the case of clause (3c) of the definition of “Benchmark Transition Event,” the first date of the publicon which such Benchmark (or the published component used in the calculation thereof) has been determined and announced by or on behalf of the administrator of such Benchmark (or such component thereof) or the regulatory supervisor for the administrator of such Benchmark (or such component thereof) to be non-representative; provided that such non-representativeness, non-compliance or non-alignment will be determined by reference to the most recent statement or publication of information referenced thereinin such clause (c) and even if any Available Tenor of such Benchmark (or such component thereof) continues to be provided on such date.

For the avoidance of doubt, the “Benchmark Replacement Date” will be deemed to have occurred in the case of clause (a) or (b) with respect to any Benchmark upon the occurrence of the applicable event or events set forth therein with respect to all then-current Available Tenors of such Benchmark (or the published component used in the calculation thereof).

Benchmark Transition Event” means the occurrence of one or more of the following events with respect to LIBORthe then-current Benchmark:

(1a) a public statement or publication of information by or on behalf of the administrator of LIBORsuch Benchmark (or the published component used in the calculation thereof) announcing that such administrator has ceased or will cease to provide LIBORall Available Tenors of such Benchmark (of such component thereof), permanently or indefinitely,; provided that, at the time of such statement or publication, there is no successor administrator that will continue to provide LIBORany Available Tenor of such Benchmark (or such component thereof);

(2b) a public statement or publication of information by the regulatory supervisor for the administrator of LIBORsuch Benchmark (or the published component used in the calculation thereof), the U.S. Federal Reserve SystemBoard, the Federal Reserve Bank of New York, an insolvency official with jurisdiction over the administrator for LIBORsuch Benchmark (or such component), a resolution authority with jurisdiction over the administrator for LIBORsuch Benchmark (or such component) or a court or an entity with similar insolvency or resolution authority over the administrator for LIBORsuch Benchmark (or such component), which states that the administrator of LIBORsuch Benchmark (or such component) has ceased or will cease to provide LIBORall Available Tenors of such Benchmark (or such component) permanently or indefinitely,; provided that, at the time of such statement or publication, there is no successor administrator that will continue to provide LIBORany Available Tenor of such Benchmark (or such component); or

(3c) a public statement or publication of information by or on behalf of the administrator of such Benchmark (or the published component used in the calculation thereof) or the regulatory supervisor for the administrator of LIBOR announcing that LIBOR is no longersuch Benchmark (or such component) announcing that all Available Tenors of such Benchmark (or such component thereof) are not, or as of a specified future date, will not be, representative.

 

A-4


For the avoidance of doubt, a “Benchmark Transition Event” will be deemed to have occurred with respect to any Benchmark if a public statement or publication of information set forth above has occurred with respect to each then-current Available Tenor of such Benchmark (or the published component used in the calculation thereof).

Benchmark Transition Start Date” means (a), in the case of a Benchmark Transition Event, the earlier of (ia) the applicable Benchmark Replacement Date and (iib) if such Benchmark Transition Event is a public statement or publication of information of a prospective event, the 90th day prior to the expected date of such event as of such public statement or publication of information (or if the expected date of such prospective event is fewer than 90 days after such statement or publication, the date of such statement or publication) and (b) in the case of an Early Opt-in Election, the date specified by the Credit Facility Agent or the Required Lenders, as applicable, with the consent of the Borrower (not to be unreasonably withheld, conditioned or delayed), by notice to the Credit Facility Agent (in the case of such notice by the Required Lenders) and the Lenders..

Benchmark Unavailability Period” means, if a Benchmark Transition Event and its related Benchmark Replacement Date have occurred with respect to LIBOR and solely to the extent that LIBOR has not been replaced with a Benchmark Replacement, the period (xif any) (a) beginning at the time that sucha Benchmark Replacement Date has occurred if, at such time, no Benchmark Replacement has replaced LIBORthe then-current Benchmark for all purposes hereunder and under any Finance Document in accordance with Section 5.07 (Effect ofReplacement Benchmark Transition EventSetting ) and (yb) ending at the time that a Benchmark Replacement has replaced LIBORthe then-current Benchmark for all purposes hereunder pursuant toand under any Finance Document in accordance with Section 5.07 (Effect ofReplacement Benchmark Transition EventSetting).

Breakage Costs” means the amount (if any) by which:

(a) the interest that would have accrued on the principal amount of a LIBOR Loan had a Breakage Event not occurred calculated at LIBOR that would have been applicable to such LIBOR Loan for the period from the date of such Breakage Event to the last day of the then current Interest Period therefor (or, in the case of a failure to borrow, convert or continue a LIBOR Loan, for the period that would have been the Interest Period for such LIBOR Loan);

exceeds:

(b) the interest that would accrue on such principal amount for such period at the interest rate which the relevant Term Lender would bid were it to bid, at the commencement of such period, for deposits in Dollars of a comparable amount and period from other banks in the LIBOR market.

Breakage Event” has the meaning provided in Section 5.05 (Funding Losses).

 

A-5


Commitment” means, as context requires, a Term Loan Commitment, a Working Capital Commitment or both.

Commitment Fees” has the meaning provided in Section 4.15(b) (Fees).

Commitment Percentage” means (i) as to any Working Capital Lender at any time, the percentage that such Working Capital Lender’s Working Capital Commitment less its Working Capital Commitment Exposure then constitutes of the Aggregate Working Capital Commitment less the total Working Capital Commitment Exposure of all Working Capital Lenders, (ii) as to any Term Lender at any time, the percentage of such Term Lender’s Term Loan Commitment constitutes of the Aggregate Term Loan Commitment and (iii) as to any Issuing Bank at any time, the percentage that such Issuing Bank’s Issuing Bank Limit less the stated amount of Letters of Credit issued by such Issuing Bank then constitutes of the aggregate Issuing Bank Limits for all Issuing Banks less the total stated amount of Letters of Credit issued by all Issuing Banks.

Communications” has the meaning provided in Section 11.10(d) (Notices and Other Communications).

Conforming Changes” means, with respect to either the use or administration of Adjusted Term SOFR or the use, administration, adoption or implementation of any Benchmark Replacement, any technical, administrative or operational changes (including changes to the definition of “Base Rate,” the definition of “Business Day,” the definition of “U.S. Government Securities Business Day,” the definition of “Interest Period” or any similar or analogous definition (or the addition of a concept of “interest period”), timing and frequency of determining rates and making payments of interest, timing of borrowing requests or prepayment, conversion or continuation notices, the applicability and length of lookback periods, the applicability of Section 5.05 (Funding Losses) and other technical, administrative or operational matters) that the Credit Facility Agent decides may be appropriate to reflect the adoption and implementation of any such rate or to permit the use and administration thereof by the Credit Facility Agent in a manner substantially consistent with market practice (or, if the Credit Facility Agent decides that adoption of any portion of such market practice is not administratively feasible or if the Credit Facility Agent determines that no market practice for the administration of any such rate exists, in such other manner of administration as the Credit Facility Agent decides is reasonably necessary in connection with the administration of this Agreement and the other Finance Documents).

Contingency Reserve Term Loan Commitment” means the commitment of a Term Lender to make or otherwise fund a Term Loan pursuant to Section 2.01(a)(ii) (Term Loans), as set forth opposite the name of such Term Lender in the column entitled “Contingency Reserve Term Loan Commitment” in Schedule I (Lenders, Commitment) or if such Term Lender has entered into one or more Lender Assignment Agreements, set forth opposite the name of such Term Lender and any assignor Term Lender in the Register maintained by the Credit Facility Agent pursuant to Section 2.06(f) (Funding), as the same may be reduced in accordance with Section 2.07 (Termination or Reduction of Commitments), and “Contingency Reserve Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

 

A-6


Coordinating Lead Arranger” means Industrial and Commercial Bank of China, New York Branch, not in its individual capacity but as coordinating lead arranger hereunder.

Credit Facility Agent” has the meaning provided in the preamble.

Credit Facility Secured Parties” means the Lenders, the Issuing Banks, the Credit Facility Agent, the Collateral Agent and each of their respective successors and permitted assigns, in each case in connection with the Credit Facility Agreement.

Defaulting Lender” means a Lender which (a) has defaulted in its obligations to fund all or any portion of any Term Loan or otherwise failed to comply with its obligations under Section 2.01 (Term Loans), Section 2.03 (Working Capital Loans), Section 2.06 (Funding) or Section 3.02 (Reimbursement to Issuing Banks), unless (x) such default or failure is no longer continuing or has been cured within three (3) Business Days after such default or failure or (y) such Lender notifies the Credit Facility Agent and the Borrower in writing that such failure is the result of such Lender’s good faith determination that one or more conditions precedent to funding (each of which conditions precedent, together with any applicable default, shall be specifically identified in such writing) has not been satisfied, (b) has notified the Borrower and/or the Credit Facility Agent that it does not intend to comply with its obligations under Section 2.01 (Term Loans), Section 2.03 (Working Capital Loans), Section 2.06 (Funding) or Section 3.02 (Reimbursement to Issuing Banks) or has made a public statement to that effect, (c) has failed, within three (3) Business Days, after written request by the Credit Facility Agent or the Borrower, to confirm in writing to the Credit Facility Agent and the Borrower that it will comply with its prospective funding obligations under Section 2.03 (Working Capital Loans), Section 2.06 (Funding) or Section 3.02 (Reimbursement to Issuing Banks) (provided that such Lender shall cease to be a Defaulting Lender pursuant to this clause (c) upon receipt of such written confirmation by the Credit Facility Agent and the Borrower), (d) has, or has a direct or indirect parent company that has, other than via Undisclosed Administration, (x) become the subject of a Bankruptcy Proceeding, or (y) had appointed for it a receiver, custodian, conservator, trustee, administrator, assignee for the benefit of creditors or similar Person charged with reorganization or liquidation of its business or assets, including the Federal Deposit Insurance Corporation or any other state or federal regulatory authority acting in such a capacity or (e) has become the subject of a Bail-In Action; provided that, for the avoidance of doubt, a Lender shall not be a Defaulting Lender solely by virtue of (i) the ownership or acquisition of any equity interest in that Lender or any direct or indirect parent company thereof by a Governmental Authority or (ii) in the case of a solvent Person, the precautionary appointment of an administrator, guardian, custodian or other similar official by a Governmental Authority under or based on the law of the country where such Person is subject to home jurisdiction supervision if Government Rule requires that such appointment not be publicly disclosed; in each case, where such action does not result in or provide such Lender with immunity from the jurisdiction of courts within the United States or from the enforcement of judgments or writs of attachment on its assets or permit such Lender (or such Governmental Authority) to reject, repudiate, disavow or disaffirm any contracts or agreements made with such Lender. Any determination by the Credit Facility Agent that a Lender is a Defaulting Lender under any one or more of the clauses above shall be conclusive and binding absent manifest error, and such Lender shall be deemed to be a Defaulting Lender upon delivery of written notice of such determination to the Borrower and each Lender.

 

A-7


Documentation Bank” means Natixis, New York Branch and Sumitomo Mitsui Banking Corporation, in each case, not in its individual capacity, but as documentation bank.

Early Opt-in Election” means the occurrence of:

(1) (i) a determination by the Credit Facility Agent or (ii) a notification by the Required Lenders to the Credit Facility Agent (with a copy to the Borrower) that the Required Lenders have determined that U.S. dollar-denominated syndicated credit facilities being executed at such time, or that include language similar to that contained in Section 5.07 (Effect of Benchmark Transition Event), are being executed or amended, as applicable, to incorporate or adopt a new benchmark interest rate to replace LIBOR, and

(2) (i) the election by the Credit Facility Agent or (ii) the election by the Required Lenders, in each case, with the consent of the Borrower (not to be unreasonably withheld, conditioned or delayed), to declare that an Early Opt-in Election has occurred and the provision, as applicable, by the Credit Facility Agent of written notice of such election to the Borrower and the Lenders or by the Required Lenders of written notice of such election to the Credit Facility Agent.

Eligible Assignee” means (a) an existing Lender, (b) any Affiliate of a Lender, (c) any Approved Fund with respect to a Lender or (d) any commercial bank, insurance company, investment or mutual fund or other entity that is an “accredited investor” (as defined in Regulation D under the Securities Act) and which extends credit or buys loans (excluding in each such case any Disqualified Institution or any Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof); provided that for any assignment, novation or transfer during the Term Loan Availability Period (or in the event of an assignment of a Working Capital Commitment, the Working Capital Availability Period) made in reliance on clause (b) or (c) above, such Lender or its rated Affiliate shall have agreed in writing with the Borrower to remain obligated to promptly fund any duly requested disbursement of the Commitment assigned, novated or transferred to such assignee or transferee (or any part thereof) should such assignee or transferee default in its obligation to fund any portion of the Commitment assigned or transferred to it.

Federal Funds Effective Rate” means, for any day, the weighted average (rounded upwards, if necessary, to the nearest 1/100 of 1%) of the rates on overnightrate calculated by the Federal Reserve Bank of New York based on such day’s federal funds transactions with members ofby depositary institutions, as determined in such manner as shall be set forth on the Federal Reserve System, asBank of New York’s website from time to time, and published on the next succeeding Business Day by the Federal Reserve Bank of New York, or, if such rate is not so published for any day that is a Business Day, the average (rounded upwards, if necessary, to the next 1/100 of 1%) of the quotations for such day for such transactions received by the Intercreditor Agent from three federal funds brokers of recognized standing selected by it. as the federal funds effective rate. If the Federal Funds Effective Rate as so determined would be less than zero, such rate shall be deemed to be zero for the purposes of this Agreement.

 

A-8


Federal Reserve Bank of New York’s WebsiteBoard” means the websiteBoard of Governors of the Federal Reserve Bank of New York at http://www.newyorkfed.org, or any successor source.System of the United States.

Fees” means, collectively, each of the fees payable by the Borrower for the account of any Lender, any Issuing Bank or the Credit Facility Agent pursuant to Section 4.15 (Fees).

Final Maturity Date” means August 19, 2026.

First Repayment Date” has the meaning provided in Section 4.01(b) (Repayment of Term Loans).

Floor” means a rate of interest equal to 0.0%.

Fronted Letter of Credit” means a Letter of Credit other than a Non-Fronted Letter of Credit.

Fronting Exposure” means, at any time there is a Defaulting Lender, with respect to any Issuing Bank, such Defaulting Lender’s pro rata share of outstanding LC Exposure with respect to Letters of Credit issued by such Issuing Bank, other than LC Exposure as to which such Defaulting Lender’s participation obligation has been reallocated to other Working Capital Lenders or cash collateralized in accordance with the terms hereof.

Fronting Fee” has the meaning provided in Section 4.15(d) (Fees).

Fronting Limit” means, at any time, with respect to any Issuing Bank, the amount set forth opposite the name of such Issuing Bank in the column entitled “Fronting Limit” on Schedule II (Issuing Bank Limits), or, in the case of any Working Capital Lender that becomes an Issuing Bank hereunder pursuant to Section 3.05 (Resignation as an Issuing Bank) or otherwise, such amount as set forth in the agreement evidencing the appointment of such Working Capital Lender as an Issuing Bank.

Guarantee” means the guarantee issued pursuant to the Common Security and Account Agreement by the Guarantor. The terms “Guarantee” and “Guaranteed” used as verbs shall have correlative meanings.

Illegality Notice” has the meaning provided in Section 5.01 (Illegality).

Incremental Amendment” has the meaning given in Section 2.09(c) (Incremental Commitments).

Incremental Lender/Issuing Bank” has the meaning given in Section 2.09(b) (Incremental Commitments).

 

A-9


Initial Coordinating Lead Arranger” means Banco Santander, S.A., New York Branch, Bank of America, N.A., The Bank of Nova Scotia, Houston Branch, Goldman Sachs Bank USA, ING Capital LLC, JPMorgan Chase Bank, N.A., Mizuho Bank, Ltd., Morgan Stanley Senior Funding, Inc., Natixis, New York Branch, Nomura Securities International, Inc., Royal Bank of Canada and Sumitomo Mitsui Banking Corporation, in each case, not in its individual capacity, but as initial coordinating lead arranger hereunder.

Intercompany Loan Agreement” has the meaning provided in the recitals.

Interest Payment Date” has the meaning provided in Section 4.04(a) (Interest Payment Dates).

Interest Period” means, with respect to any LIBOR Loan, the period beginning on the date on which such LIBOR Loan is made pursuant to Section 2.06(a) (Funding) or on the last day of the immediately preceding Interest Period therefor, as applicable, and ending on the numerically corresponding day in the calendar month that is in connection with a SOFR Loan, subject, in each case to the availability thereof, an interest period of one (1), two (2), three (3) or six (6) months thereafter (or, if available to all applicable Lenders, nine (9) or twelve (12) months), in each case as the Borrower may select in the relevantsuch other periods as may be agreed by the Credit Facility Agent (including with respect to the Applicable Margin agreed to by all the Lenders with respect to any such Interest Period)), as selected by the Borrower in the applicable Disbursement Request or Interest Period Notice, (a) initially, commencing on the Initial Closing Date and ending on June 30, 2022; and (b) thereafter, commencing on the day on which the immediately preceding Interest Period expires; provided, however, that, (i) the Interest Period for any Advance shall commence on the date of the Advance (or the date of the conversion of any Base Rate Loans to LIBOR Loans in accordance with this Agreement) and shall extend up to (but not include) the first Interest Payment Date following the date of the Advance, (ii) if such Interestif an Interest Period would otherwise endexpire on a day that is not a Business Day, such Interest Period shall endexpire on the next followingsucceeding Business Day (unless such next followingno further Business Day is in a different calendaroccurs in such month, in which case such Interest Period shall endexpire on the immediately preceding Business Day),; (iiiii) any Interest Period that begins on the last Business Day of a calendar month (or on a day for which there is no numerically corresponding day in the calendar month at the end of such Interest Period) shall, subject to clause (iii) of this definition, end on the last Business Day of thea calendar month at the end of such Interest Period,; (iviii) no Interest Period may end later thanshall extend beyond the Final Maturity Date, and (v) any Interest Period for a Loan which would otherwise end after the Final Maturity Date shall end on the Final Maturity Date.; and (iv) no tenor that has been removed from this definition pursuant to Section 5.07(d) (Benchmark Replacement Setting – Unavailability of Tenor Benchmark) shall be available for specification in such Disbursement Request or Interest Period Notice.

Interest Period Notice” means a notice in substantially the form attached hereto as Exhibit F (Form of Interest Period Notice), executed by an Authorized Officer of the Borrower or, in the case of an Advance, a Disbursement Request.

ISP98” has the meaning given in Section 3.01(g) (Letters of Credit).

 

A-10


Issuing Bank” means each Working Capital Lender identified as an “Issuing Bank” on Schedule II (Issuing Bank Limits) and any other Working Capital Lender designated by the Borrower after the date hereof that has, or whose credit support provider has, a credit rating of A3 or higher by Moody’s, A- or higher by S&P or an equivalent rating by another nationally-recognized credit rating agency, and that has agreed in writing in its sole discretion to accept such designation as an Issuing Bank and to be bound by all of the terms contained in this Agreement and the other Finance Documents binding on an Issuing Bank in such capacity (provided that, a copy of such agreement has been delivered to the Credit Facility Agent), it being understood that such agreement may contain additional conditions to, or limitations on, such Issuing Bank’s obligation to issue Letters of Credit hereunder (including limits on the aggregate stated amount of Letters of Credit at any one time outstanding that may be issued by such Issuing Bank), and any such conditions or limitations are hereby incorporated by reference into this Agreement to the same extent and with the same force as if fully set forth herein. Each reference to an Issuing Bank contained in this Agreement and the other Finance Documents shall be deemed to refer to the applicable Working Capital Lender solely in its capacity as the issuer of Letters of Credit hereunder and not in its capacity as a Working Capital Lender, and each reference to a Working Capital Lender contained in this Agreement and the other Finance Documents shall be deemed to refer to such Working Capital Lender in its capacity as such and not in its capacity (if applicable) as an Issuing Bank.

Issuing Bank Limit” means the limitation on the obligation of each Issuing Bank to issue Letters of Credit as identified in the column “Issuing Bank Limit” on Schedule II (Issuing Bank Limits) with respect to each Issuing bank.

LC Available Amount” means, for any Letter of Credit on any date of determination, the maximum amount available to be drawn under such Letter of Credit at any time on or after such date (assuming the satisfaction of all conditions for drawing enumerated therein).

LC Cash Collateral Account” means, an interest-bearing cash collateral account established upon the occurrence of a Loan Facility Event of Default by the Credit Facility Agent in its name for the benefit of the Working Capital Lenders and Issuing Banks, subject to the terms of this Agreement and the Common Security and Account Agreement.

LC Exposure” means, as of any time of determination and with respect to any Issuing Bank, the sum of (a) the aggregate undrawn amount of the outstanding Letters of Credit issued by such Issuing Bank at such time plus (b) the aggregate amount of all LC Loans made by such Issuing Bank and in which no other Working Capital Lender is required to participate that have not yet been repaid at such time plus (c) the aggregate amount of LC Reimbursement Payments that the Borrower has not yet repaid and have not yet been converted to LC Loans as of such time.

LC Fee” has the meaning provided in Section 4.15(c) (Fees).

LC Loan” means a loan by a Working Capital Lender to the Borrower deemed made pursuant to Section 3.02(c) and Section 3.02(f) (Reimbursement to Issuing Banks).

 

A-11


LC Payment Notice” has the meaning provided in Section 3.02(a) (Reimbursement to Issuing Banks).

LC Reimbursement Payment” has the meaning provided in Section 3.02(b) (Reimbursement to Issuing Banks).

Lender” means, as context requires, a Term Lender, a Working Capital Lender, or both.

Lender Assignment Agreement” means a Lender Assignment Agreement, substantially in the form of Exhibit G (Form of Lender Assignment Agreement).

Letter of Credit” means a standby letter of credit substantially in a form attached hereto as (i) Exhibit E-1 (Form of Letter of Credit – TETCO), if such letter of credit is to be issued to the counterparty under the agreement described in clause (a) of the definition of “Gas Transportation Agreements” in the Common Terms Agreement, (ii) Exhibit E-2 (Form of Letter of Credit – ANR), if such letter of credit is to be issued to the counterparty under the agreement described in clause (b) of the definition of “Gas Transportation Agreements” in the Common Terms Agreement (which forms are acceptable to the Issuing Banks), (iii) Exhibit E-3 (Form of Letter of Credit – EnLink), if such letter of credit is to be issued to one of the counterparties under the agreement described in clause (c) of the definition of “Gas Transportation Agreements” in the Common Terms Agreement or (iv) such form as is otherwise reasonably acceptable to the Issuing Bank issuing such letter of credit, in each case issued pursuant to Section 3.01 (Letters of Credit) and in accordance with the policies and procedures of such Issuing Bank.

LIBOR” means, in respect of any Loan, if applicable, and in relation to any Relevant Interest Period, the percentage rate per annum as determined by the Credit Facility Agent to be equal to:

 

  (a)

the offered rate per annum for deposits in US Dollars which is quoted on the Screen Rate for the purpose of displaying London interbank offered rates of major banks for deposits in US Dollars as administered by ICE Benchmark Administration Limited (or any other Person which takes over the administration of that rate) in US Dollars, (before any correction, recalculation or republication by the administration) for a period of six months or such other period that corresponds to the Relevant Interest Period, at approximately 11:00 a.m. London time on the date that is two (2) Business Days prior to the first day of the Relevant Interest Period; or

 

  (b)

if no such quotation so appears, and no other page is so agreed between the Borrower and the Intercreditor Agent at or about such time, the arithmetic mean (rounded upwards, if necessary, to five decimal places) of the rates per annum for deposits in US Dollars for a period of six months or such other period that corresponds to the Relevant Interest Period (in each case as supplied to the Intercreditor Agent at its request), at which rates at least three of the Reference Banks were offering to leading banks in the London interbank market, or as otherwise defined in the this Agreement; provided, in each case, that if any such rate is below zero, LIBOR will be deemed to be zero.

 

A-12


LIBOR Loan” means any Loan bearing interest at a rate determined by reference to LIBOR and the provisions of Article II (Commitments and Advances) and Article IV (Repayments, Prepayments, Interest and Fees).

Loan” means, as context requires, a Term Loan, a Working Capital Loan, an LC Loan or each of the foregoing.

Loan Obligations” means, collectively, all Senior Debt Obligations arising under the Credit Facility Agreement.

Maximum Rate” has the meaning provided in Section 11.08 (Interest Rate Limitation).

Non-Consenting Lender” means in respect of a Lender, if such Lender has failed to consent to a proposed amendment, waiver, consent or termination which pursuant to the terms of Section 11.01 (Decisions, Amendments, Etc.) requires the consent of all of the Lenders or all affected Lenders and with respect to which Lenders representing at least 50% of the sum of (i) the aggregate undisbursed Commitments plus (ii) the then aggregate outstanding principal amount of the Loans (excluding in each such case any Lender that is a Defaulting Lender or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, a Collateral Party, the Sponsor or any of Sponsor’s Affiliates, and each Commitment and any outstanding principal amount of any Loan of any such Term Lender) or Lenders affected by such proposed amendment, waiver, consent or termination, as the case may be, shall have granted their consent.

Non-Defaulting Lender” means, at any time, a Lender that is not a Defaulting Lender. “Non-Fronted LC Amount” has the meaning provided in Section 3.01(f) (Letters of Credit).

Non-Fronted Letter of Credit” means a Letter of Credit identified by the Borrower as such in the Request for Issuance.

Non-Fronting Limit” means, at any time, with respect to any Issuing Bank, the amount set forth opposite the name of such Issuing Bank in the column entitled “Non-Fronting Limit” on Schedule II (Issuing Bank Limits), or, in the case of any Working Capital Lender that becomes an Issuing Bank hereunder pursuant to Section 3.05 (Resignation as an Issuing Bank) or otherwise, such amount as set forth in the agreement evidencing the appointment of such Working Capital Lender as an Issuing Bank, as the same may be (a) reduced from time to time in accordance with Section 2.07 (Termination or Reduction of Commitments), (b) increased from time to time in accordance with Section 2.09 (Incremental Commitments), and (c) reduced or increased from time to time pursuant to assignments by or to such Lender pursuant to Section 11.04 (Assignments).

Note” means, as context requires, a Term Loan Note or a Working Capital Loan Note.

 

A-13


Periodic Term SOFR Determination Day” has the meaning provided in the definition of “Term SOFR.”

Pre-Completion Working Capital Loan Sublimit” means $100,000,000.

Reference Banks” means the principal London offices of each of Lloyds TSB Bank plc, JP Morgan Chase and HSBC Bank, or any other bank or financial institution as shall be specified by the Credit Facility Agent and approved by the Borrower (such approval not to be unreasonably withheld).

Register” has the meaning provided in Section 2.06(e) (Funding).

Related Parties” means, with respect to any specified Person, such Person’s Affiliates and the respective shareholders, members, partners, directors, officers, employees, agents, trustees, advisors and representatives of such Person and such Person’s Affiliates.

Relevant Governmental Body” means the Federal Reserve Board and/or the Federal Reserve Bank of New York, or a committee officially endorsed or convened by the Federal Reserve Board and/or the Federal Reserve Bank of New York or any successor thereto.

Request for Issuance” has the meaning provided in Section 3.01(a) (Letters of Credit).

Required Lenders” means at any time, the Lenders holding in excess of 50.00% of the sum of (a) the aggregate undisbursed Commitments plus (b) the then aggregate outstanding principal amount of the Loans (excluding in each such case any Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, an Affiliated Lender, and each Commitment and any outstanding principal amount of any Loan of any such Lender). Such percentage shall be calculated by dividing the number of votes cast in favor of a Decision by the total number of votes cast with respect to such Decision.

Required Term Lenders” means at any time, the Term Lenders holding in excess of 50.00% of the sum of (a) the aggregate undisbursed Term Loan Commitments plus (b) the then aggregate outstanding principal amount of the Term Loans (excluding in each such case any Term Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, a Collateral Party, the Sponsor or any of Sponsor’s Affiliates, and each Term Loan Commitment and any outstanding principal amount of any Term Loan of any such Term Lender). Such percentage shall be calculated by dividing the number of votes cast in favor of a Decision by the total number of votes cast with respect to such Decision.

Required Working Capital Lenders” means at any time, the Working Capital Lenders holding in excess of 50.00% of the sum of (a) the aggregate undisbursed Working Capital Commitments plus (b) the then-aggregate outstanding principal amount of the Working Capital Loans (excluding in each such case any Working Capital Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, a Collateral Party, the Sponsor or any of the Sponsor’s Affiliates, and each Working Capital Commitment and any outstanding principal amount of any Working Capital Loan of any such Working Capital Lender). Such percentage shall be calculated by dividing the number of votes cast in favor of a Decision by the total number of votes cast with respect to such Decision.

 

A-14


Screen Rate” means Bloomberg Page LIBOR01 (or if such page is not accessible or ceases to display, such other page on the Bloomberg Screen or on the relevant pages of such other service as may be selected by the Intercreditor Agent for purposes of displaying comparable rates).

SOFRwith respect to any day meansmeans a rate equal to the secured overnight financing rate published for such day by the Federal Reserve Bank of New York, as the administrator of the benchmark, (or a successor administrator) on the Federal Reserve Bank of New York’s Websiteas administered by the SOFR Administrator.

SOFR Administrator” means the Federal Reserve Bank of New York (or a successor administrator of the secured overnight financing rate).

SOFR Loan” means a Loan that bears interest at a rate based on Adjusted Term SOFR, other than pursuant to clause (c) of the definition of “Base Rate.”

Term Lenders” means those Term Lenders identified on Schedule I (Lenders, Commitments) and each other Person that acquires the rights and obligations of any such Term Lender in accordance with Section 11.04 (Assignments) but excluding any Person that has assigned all of its rights and obligations under the Credit Facility Agreement in accordance with Section 11.04 (Assignments) (other than in connection with the sale of participations) and Participants.

Term Loan” means, with respect to each Term Lender, each advance to the Borrower of such Term Lender’s pro rata share of the Term Loan Commitment as the Borrower may request under Section 2.02 (Term Loan Availability) and the applicable Disbursement Request.

Term Loan Advance” means each Advance of Term Loans by the Term Lenders (or the Credit Facility Agent on their behalf) on any single date to the Borrower in accordance with Section 2.06 (Funding) and Article VII (Conditions Precedent).

Term Loan Availability Period” has the meaning provided in Section 2.02 (Term Loan Availability).

Term Loan Commitment” means the Base Term Loan Commitment and/or the Contingency Reserve Term Loan Commitment, as the case may be, and “Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

Term Loan Commitment Fee” has the meaning provided in Section 4.15(a) (Fees).

Term Loan Notes” means the promissory notes of the Borrower, substantially in the form of Exhibit B-1 (Form of Term Loan Note) evidencing Term Loans, in each case duly executed and delivered by an Authorized Officer of the Borrower in favor of each Term Lender that requests a Term Loan Note, including any promissory notes issued by the Borrower in connection with assignments of any Term Loan of the Term Lenders.

 

A-15


Term SOFR” means:

(a) for any calculation with respect to a SOFR Loan, the Term SOFR Reference Rate for a tenor comparable to the applicable Interest Period on the day (such day, the “Periodic Term SOFR Determination Day”) that is two (2) U.S. Government Securities Business Days prior to the first day of such Interest Period, as such rate is published by the Term SOFR Administrator; provided that, if as of 5:00 p.m. (New York City time) on any Periodic Term SOFR Determination Day the Term SOFR Reference Rate for the applicable tenor has not been published by the Term SOFR Administrator and a Benchmark Replacement Date with respect to the Term SOFR Reference Rate has not occurred, then Term SOFR will be the Term SOFR Reference Rate for such tenor as published by the Term SOFR Administrator on the first preceding U.S. Government Securities Business Day for which such Term SOFR Reference Rate for such tenor was published by the Term SOFR Administrator so long as such first preceding U.S. Government Securities Business Day is not more than three (3) U.S. Government Securities Business Days prior to such Periodic Term SOFR Determination Day; and

(b) for any calculation with respect to a Base Rate Loan on any day, the Term SOFR Reference Rate for a tenor of one month on the day (such day, the “Base Rate Term SOFR Determination Day”) that is two (2) U.S. Government Securities Business Days prior to such day, as such rate is published by the Term SOFR Administrator; provided that, if as of 5:00 p.m. (New York City time) on any Base Rate Term SOFR Determination Day the Term SOFR Reference Rate for the applicable tenor has not been published by the Term SOFR Administrator and a Benchmark Replacement Date with respect to the Term SOFR Reference Rate has not occurred, then Term SOFR will be the Term SOFR Reference Rate for such tenor as published by the Term SOFR Administrator on the first preceding U.S. Government Securities Business Day for which such Term SOFR Reference Rate for such tenor was published by the Term SOFR Administrator so long as such first preceding U.S. Government Securities Business Day is not more than three (3) U.S. Government Securities Business Days prior to such Base Rate Term SOFR Determination Day;

provided further that, if Term SOFR determined as provided above (including pursuant to the proviso under clause (a) or clause (b) above) shall ever be less than zero, then Term SOFR shall be deemed to be zero.

Term SOFR Adjustment” means, with respect to Term SOFR, for an Interest Period of a duration of (a) one-month 0.10% (10 basis points), (b) three-months, 0.15% (15 basis points) and (c) six-months, 0.25% (25 basis points).

Term SOFR Administrator” means CME Group Benchmark Administration Limited (CBA) (or a successor administrator of the Term SOFR Reference Rate selected by the Credit Facility Agent in its reasonable discretion).

 

A-16


Term SOFR Reference Rate” means the forward-looking term rate based on SOFR that has been selected or recommended by the Relevant Governmental Body.

Trade Date” has the meaning provided in Section 11.04(b) (Assignments).

Type” means, when used in reference to:

(a) any Loan or Advance, or the Loans constituting such Advance, Term Loans and/or Working Capital Loans (or any Type thereof) as the context requires; and

(b) any Commitment, a Term Loan Commitment and/or a Working Capital Commitment as the context requires.

UCP 600” has the meaning provided in Section 3.01(g)(iii) (Letters of Credit).

Unadjusted Benchmark Replacement” means the Benchmark Replacement excluding the Benchmark Replacement Adjustment.

Undisclosed Administration” means, in relation to a Lender or its direct or indirect parent company, the appointment of an administrator, provisional liquidator, conservator, receiver, trustee, custodian, or other similar official by a supervisory authority or regulator under or based on the law in the country where such Lender or such parent company is subject to home jurisdiction supervision, if applicable law requires that such appointment not be publicly disclosed.

“U.S. Government Securities Business Day” means any day except for (a) a Saturday, (b) a Sunday or (c) a day on which the Securities Industry and Financial Markets Association recommends that the fixed income departments of its members be closed for the entire day for purposes of trading in United States government securities.

Working Capital Advance” means each Advance of Working Capital Loans by or on behalf of the Working Capital Lenders on any single date to the Borrower in accordance with Section 2.06 (Funding) and Article VII (Conditions Precedent).

Working Capital Availability Period” means the Closing Date until the Working Capital Loan Termination Date.

Working Capital Commitment” means, with respect to each Working Capital Lender, the commitment of such Working Capital Lender to (i) make Working Capital Loans and (ii) make LC Loans in respect of Fronted Letters of Credit and Non-Fronted Letters of Credit (subject to such Working Capital Lender’s Non-Fronting Limit as set forth opposite the name of such Working Capital Lender in the column entitled “Non-Fronting Limit” on Schedule II (Issuing Bank Limits)), in an aggregate amount not to exceed the amount set forth opposite the name of such Working Capital Lender in the column entitled “Total Working Capital Commitment” in Schedule I (Lenders, Commitments), or if such Working Capital Lender has entered into one or more Lender Assignment Agreements, set forth opposite the name of such Working Capital Lender in the Register maintained by the Credit Facility Agent as such Working Capital Lender’s

 

A-17


commitment, as the same may be (a) reduced from time to time in accordance with Section 2.07 (Termination or Reduction of Commitments), (b) increased from time to time in accordance with Section 2.09 (Incremental Commitments), (c) reduced or increased from time to time pursuant to assignments by or to such Working Capital Lender pursuant to Section 11.04 (Assignments) and (d) utilized, as of the applicable date of determination, in the amount of such Working Capital Lender’s Working Capital Commitment Exposure.

Working Capital Commitment Fee” has the meaning provided in Section 4.15(b) (Fees).

Working Capital Commitment Increase” has the meaning provided in Section 2.09(a) (Incremental Commitments).

Working Capital Commitment Increase Notice” has the meaning provided in Section 2.09(a) (Incremental Commitments).

Working Capital Commitment Exposure” means as of any time of determination and with respect to each Working Capital Lender, the sum of (i) the principal amount of its Working Capital Loans outstanding, plus (ii) the principal amount of its LC Loans outstanding, plus (iii) in the case of each Working Capital Lender that is an Issuing Bank, the aggregate undrawn amount of the outstanding Letters of Credit issued by it (excluding the aggregate amount thereof in respect of which other Working Capital Lenders are required to participate), plus (iv) aggregate LC Reimbursement Payments that have not yet converted to LC Loans under the outstanding Letters of Credit issued by it (excluding the aggregate amount thereof in respect of which other Working Capital Lenders are required to participate) plus (v) the aggregate amount of such Working Capital Lender’s participations in Letters of Credit issued by other Issuing Banks.

Working Capital Facility” has the meaning provided in the preamble.

Working Capital Lender Payment Notice” has the meaning provided in Section 3.02(c) (Reimbursement to Issuing Banks).

“Working Capital Lenders” means those Working Capital Lenders identified on Schedule I (Lenders, Commitments) and each other Person that acquires the rights and obligations of any such Working Capital Lender in accordance with Section 11.04 (Assignments) but excluding any Person that has assigned all of its rights and obligations under the Credit Facility Agreement in accordance with Section 11.04 (Assignments) (other than in connection with the sale of participations) and Participants.

Working Capital Loan” has the meaning provided in Section 2.04(a) (Working Capital Loan Availability).

Working Capital Loan Availability Period” has the meaning provided in Section 2.04(a) (Working Capital Loan Availability).

Working Capital Loan Availability Date” means the date, no earlier than the date that is thirty (30) days prior to the date on which the Borrower reasonably anticipates that the LPS1 Substantial Completion Date (as defined in the EPC Contract) will occur, as certified in writing by the Borrower to the Credit Facility Agent (and confirmed in writing by the Independent Engineer).

 

A-18


Working Capital Loan Note” means the promissory notes of the Borrower, substantially in the form of Exhibit B-2 (Form of Working Capital Note) evidencing Working Capital Loans, in each case duly executed and delivered by an Authorized Officer of the Borrower in favor of each Working Capital Lender that requests a Working Capital Loan Note, including any promissory notes issued by the Borrower in connection with assignments of any Working Capital Loan of the Working Capital Lenders.

Working Capital Loan Termination Date” has the meaning provided in Section 2.04(a) (Working Capital Loan Availability).

 

A-19


EXHIBIT B-1 TO

CREDIT FACILITY AGREEMENT

Form Of Term Loan Note

[Omitted]


EXHIBIT B-2 TO

CREDIT FACILITY AGREEMENT

Form Of Working Capital Loan Note

[Omitted]


EXHIBIT C TO

CREDIT FACILITY AGREEMENT

[Reserved]


EXHIBIT D TO

CREDIT FACILITY AGREEMENT

[Reserved]


EXHIBIT E-1 TO

CREDIT FACILITY AGREEMENT

Form Of Letter of Credit – TETCO

[Omitted]


EXHIBIT E-2 TO

CREDIT FACILITY AGREEMENT

Form Of Letter of Credit – ANR

[Omitted]


EXHIBIT E-3 TO

CREDIT FACILITY AGREEMENT

Form Of Letter of Credit – EnLink

[Omitted]


EXHIBIT F TO

CREDIT FACILITY AGREEMENT

Form Of Interest Period Notice

[Omitted]


EXHIBIT G TO

CREDIT FACILITY AGREEMENT

Form Of Lender Assignment Agreement

[Omitted]

Exhibit 10.81

Execution Version

SIXTH AMENDMENT TO THE COMMON TERMS AGREEMENT AND FOURTH

AMENDMENT TO THE COMMON SECURITY AND ACCOUNT AGREEMENT

This SIXTH AMENDMENT TO THE COMMON TERMS AGREEMENT AND FOURTH AMENDMENT TO THE COMMON SECURITY AND ACCOUNT AGREEMENT (this “Amendment”), dated as of June 30, 2023 (the “Effective Date”), is in respect of (a) the Common Terms Agreement, dated as of August 19, 2019, by and among Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Borrower”), TransCameron Pipeline, LLC (the “Guarantor”), Natixis, New York Branch, as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties (in such capacity, the “Credit Facility Agent”), each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Mizuho Bank, Ltd., as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”), as amended by that certain Consent and Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of December 28, 2020, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, that certain Second Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of January 26, 2021, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, that certain Third Amendment to the Common Terms Agreement, First Amendment to the Common Security and Account Agreement and Consent to the Credit Facility Agreement, dated as of May 25, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, Mizuho Bank (USA), as Collateral Agent (in such capacity, the “Collateral Agent”) and Intercreditor Agent, that certain Fourth Amendment to the Common Terms Agreement and Second Amendment to the Credit Facility Agreement, dated as of October 12, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, and that certain Fifth Amendment to the Common Terms Agreement and Third Amendment to the Common Security and Account Agreement, dated February 27, 2023, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, Intercreditor Agent and Collateral Agent (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”) and (b) the Common Security and Account Agreement, dated as of August 19, 2019, by and among the Borrower, the Guarantor, the Senior Creditor Group Representatives from time to time party thereto, the Intercreditor Agent, the Collateral Agent and Mizuho Bank, Ltd., as the account bank, as amended by that certain Third Amendment to the Common Terms Agreement, First Amendment to the Common Security and Account Agreement and Consent to the Credit Facility Agreement, dated as of May 25, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, the Collateral Agent and Intercreditor Agent, that certain Second Amendment to the Common Security and Account Agreement, dated as of January 9, 2023, by and among Borrower, Guarantor, the Collateral Agent and Intercreditor Agent, and that certain Fifth Amendment to the Common Terms Agreement and Third Amendment to the Common Security and Account Agreement, dated February 27, 2023, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, Intercreditor Agent and Collateral Agent (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Common Security and Account Agreement”). All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Common Terms Agreement. For all purposes of this Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.


WHEREAS, the Borrower has requested that the Credit Facility Lenders under the Credit Facility Agreement (collectively, the “Lenders” and each individually, a “Lender”), the Credit Facility Agent, the Collateral Agent and the Intercreditor Agent consent and agree to (i) amend the Common Terms Agreement and the Common Security and Account Agreement and (ii) waive the timely delivery of the certificate required by Section 11.3(j) of the Common Terms Agreement on the terms and conditions set forth herein and in accordance with Section 23.15 of the Common Terms Agreement, Section 4 of the Intercreditor Agreement, Section 7.2(a)(i)(A) (Modification Approval Levels) and 12.14 (Amendments) of the Common Security and Account Agreement.

NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1. Consent and Amendments.

1.1 Consent and Amendment to Common Terms Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, each of the Lenders party hereto, the Credit Facility Agent (at the direction of Required Lenders) and the Intercreditor Agent hereby consent and agree as follows:

(a) The definition of “Date Certain” in Section 1.3 (Definitions) of Schedule A (Common Definitions and Rules of Interpretation) to the Common Terms Agreement shall be amended and restated in its entirety as follows:

““Date Certain” means December 31, 2024; provided that if, on or prior to December 31, 2024, the Borrower certifies to the Intercreditor Agent (and the Independent Engineer reasonably concurs with such certification in writing) that (i) the only remaining condition to the Project Completion Date as of the date of delivery of such certification, other than conditions that can only be satisfied on the Project Completion Date, is the condition specified in Section 14.1(c)(iii) (Conditions to Occurrence of the Project Completion Date – Physical Completion Certificate) and (ii) the Lenders’ Reliability Test has commenced in accordance with the procedures specified in Section 12.11 (Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages) and is reasonably expected to be completed on or prior to March 31, 2025, then for all purposes under this Agreement the “Date Certain” means March 31, 2025.”

(b) Solely with respect to any Restricted Payment made pursuant to Section 11.3 (Pre-Completion Restricted Payments) of the Common Terms Agreement between the date hereof and June 30, 2023, the Borrower shall be permitted to deliver the certificate required by Section 11.3(j) (Pre-Completion Restricted Payments) of the Common Terms Agreement on the date of such Restricted Payment (in lieu of delivery at least two Business Days prior to the date of such Restricted Payment).

 

2


1.2 Administrative Amendment to Common Security and Account Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, the Collateral Agent (at the direction of the Intercreditor Agent) hereby consents and agrees to amend the Common Security and Account Agreement as follows:

““Date Certain” means December 31, 2024; provided that if, on or prior to December 31, 2024, the Borrower certifies to the Intercreditor Agent (and the Independent Engineer reasonably concurs with such certification in writing) that (i) the only remaining condition to the Project Completion Date as of the date of delivery of such certification, other than conditions that can only be satisfied on the Project Completion Date, is the condition specified in Section 14.1(c)(iii) (Conditions to Occurrence of the Project Completion Date Physical Completion Certificate) and (ii) the Lenders’ Reliability Test has commenced in accordance with the procedures specified in Section 12.11 (Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages) and is reasonably expected to be completed on or prior to March 31, 2025, then for all purposes under this Agreement the “Date Certain” means March 31, 2025.”

Section 2. Effectiveness. This Amendment shall become effective as of the date hereof subject to satisfaction of the following conditions precedent:

2.1 delivery of executed counterparts of this Amendment by each of (i) the Borrower, (ii) the Guarantor, (iii) the Intercreditor Agent, (iv) the Collateral Agent, (v) the Credit Facility Agent (who constitutes the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement)) and (vi) Lenders constituting the Required Lenders under the Credit Facility Agreement;

2.2 the Intercreditor Agent and the Credit Facility Agent shall have received an updated Construction Budget and Schedule;

2.3 the Intercreditor Agent and the Credit Facility Agent shall have received a certificate from the Borrower certifying that:

(a) since the last delivery by the Independent Engineer of the monthly construction report as provided by Section 10.4 (Construction Reports) of the Common Terms Agreement, the Borrower has not become aware of any event or circumstance the occurrence of which could reasonably be expected to (i) increase the total Project Costs materially above those set forth in the Construction Budget and Schedule (as updated pursuant to Section 2.2), or (ii) have a Material Adverse Effect;

(b)

(i) the sum of (A) amounts on deposit in the Contingency Reserve Account, (B) amounts on deposit in the Construction Account, (C) amounts on deposit in the Pre-Completion Revenues Account, and (D) the amounts of any committed, but undrawn, Senior Debt Commitment available to the Borrower equals or exceeds

 

3


(ii) the amount of funds that are, as of the date hereof, reasonably required to achieve the Project Completion Date (excluding any amounts required to be funded in the Senior Facilities Debt Service Reserve Account and each other Additional Debt Service Reserve Account (if any) (or, if the Senior Facilities Debt Service Reserve Account or any such Additional Debt Service Reserve Account is not yet required to be funded, the amount that will be required to be funded therein on the first date on which such account is required to be funded)) by the Date Certain (as amended by this Amendment) (such amount in this clause (ii), the “Required Completion Amount”);

(c) the Borrower reasonably believes that Project Completion Date shall occur on or prior to the Date Certain (as amended by this Amendment).

2.4 the Borrower has delivered to the Intercreditor Agent a certification from the Independent Engineer confirming (a) that it reasonably expects the Project Completion Date to be achieved by the Date Certain (as amended by this Amendment) and (b) the Obligors have funds equal to or in excess of the Required Completion Amount.

Section 3. Representations and Warranties. Each of the Obligors hereby represents and warrants to the Lenders, Credit Facility Agent, the Collateral Agent and Intercreditor Agent that:

3.1 upon the effectiveness of the consents and amendments set forth in Section 1, no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing or will result from the consummation of the transactions contemplated by this Amendment; and

3.2 upon the effectiveness of the consents and amendments set forth in Section 1, each of the representations and warranties of the Obligors in the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents is true and correct in all material respects except (A) for those representations and warranties that are qualified by materiality, which are true and correct in all respects on and as of the date hereof (or, if stated to have been made solely as of an earlier date, as of such earlier date) and (B) for the representations and warranties set forth in Section 5.1 (Initial Representations and Warranties of the Obligors) of the Common Terms Agreement, which were made only on the Closing Date.

Section 4. Finance Document. This Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement. Each of the parties hereto agree that (i) each reference to “Common Terms Agreement” in each Finance Document, including the Intercreditor Agreement and the Common Security and Account Agreement, shall refer to the Common Terms Agreement as amended hereby and (ii) each reference to “Common Security and Account Agreement” in each Finance Document, including the Intercreditor Agreement and the Common Terms Agreement, shall refer to the Common Security and Account Agreement as amended hereby.

Section 5. Governing Law. THIS AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA.

 

4


Section 6. Headings. All headings in this Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.

Section 7. Binding Nature and Benefit; Amendment. This Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 8. Counterparts. This Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Amendment.

Section 9. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Common Terms Agreement, the Common Security and Account Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Amendment apply to any other matters.

Section 10. E-Signature. The words “execution,” “signed,” “signature,” and words of like import in this Amendment shall be deemed to include electronic signatures or electronic records, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any legal requirements, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

Section 11. Direction to Credit Facility Agent, Intercreditor Agent and Collateral Agent.

11.1 By their signature below, each of the undersigned Credit Facility Lenders (collectively constituting the Required Lenders) instructs the Credit Facility Agent to (i) execute this Amendment and (ii) direct the Intercreditor Agent to execute this Amendment.

11.2 Based on the instructions in Section 11.1, the Credit Facility Agent, constituting the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement), hereby directs the Intercreditor Agent to execute this Amendment.

 

5


11.3 The Borrower hereby confirms that the amendment contemplated in Section 1.2 is an Administrative Decision within the meaning of Schedule 2 to the Intercreditor Agreement and hereby requests that the Intercreditor Agent provide a direction to the Collateral Agent in accordance with Section 7.2(a)(i)(A) (Modification Approval Levels) and 12.14 (Amendments) of the Common Security and Account Agreement to execute this Amendment.

11.4 Based on the certification in Section 11.3, the Intercreditor Agent hereby directs the Collateral Agent to execute this Amendment.

[Remainder of the page left intentionally blank.]

 

6


IN WITNESS WHEREOF, the Parties have caused this Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as the Borrower

By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title:  Chief Financial Officer

TRANSCAMERON PIPELINE, LLC,

as the Guarantor

By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title:  Chief Financial Officer

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

By:   /s/ Urs B. Fischer
Name: Urs B. Fischer
Title:  Executive Director
By:   /s/ Hana Beckles
Name: Hana Beckles
Title:  Director

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Intercreditor Agent

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli

Title:  Director

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK (USA),

as Collateral Agent

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli

Title:  Director

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

BANK OF AMERICA, N.A.,

as Lender

By:   /s/ Ronald E. McKaig
Name: Ronald E. McKaig

Title:  Managing Director

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

THE BANK NOVA SCOTIA, HOUSTON BRANCH,

as Lender

By:   /s/ Joe Lattanzi
Name: Joe Lattanzi

Title:  Managing Director

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

DZ BANK AG DEUTSCHE

ZENTRAL-GENOSSENSCHAFTSBANK, NEW YORK BRANCH,

as Lender

By:   /s/ Glenn R. Patterson
Name: Glenn R. Patterson

Title:  Director

By:   /s/ Zhao Liang Deng
Name: Zhao Liang Deng

Title: Assistant Vice President

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

Federated Hermes Project and Trade Finance Master Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley

Title:  Vice President

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

Federated Hermes Project and Trade Finance Tender Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley

Title:  Vice President

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

Project and Trade Finance Core Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley

Title:  Vice President

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

ING CAPITAL LLC,

as Lender

By:   /s/ Subha Pasumarti
Name: Subha Pasumarti

Title: MD

By:   /s/ Catharina Van Der Woude
Name: Catharina Van Der Woude

Title: Director

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

J.P. Morgan Chase Bank, N.A.,

as Lender

By:   /s/ Arina Mavilian
Name: Arina Mavilian

Title: Executive Director

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

KfW IPEX-Bank GmbH

as Lender

By:   /s/ Peter Eysel
Name: Peter Eysel

Title: Director

By:   /s/ Dorothee Schwenk
Name: Dorothee Schwenk

Title: Ass. Vice President

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

LANDESBANK BADEN-WÜRTTEMBERG,

New York Branch

as Lender

By:   /s/ A. Bruns
Name: A. Bruns

Title: Director

By:   /s/ O. Langel
Name: O. Langel

Title: Executive Director

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

LANDESBANK HESSEN-THÜRINGEN GIROZENTRALE, NEW YORK BRANCH,

as Lender

By:   /s/ David A. Leech
Name: David A. Leech

Title:  Vice President

By:   /s/ Raf Goebel
Name: Raf Goebel

Title:  Vice President

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MUNICH REINSURANCE AMERICA, INC.

as Lender

By:   /s/ Oliver J. Horbelt
Name: Oliver J. Horbelt
Title:  Senior Vice President and Chief Financial Officer
By:   /s/ Ganesh Narayan
Name: Ganesh Narayan
Title:  Vice President & Controller

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Lender

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title:  Director

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

NATIONAL BANK OF CANADA,

as Lender

By:   /s/ John Hunt
Name: John Hunt
Title:  Authorized Signatory
By:   /s/ Mark Williamson
Name: Mark Williamson
Title:  Authorized Signatory

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR THE NATWEST GROUP PENSION FUND (MAIN FUND SECTION),

as Lender

By:   /s/ Lisa Shaw
Name: Lisa Shaw
Title:  Attorney
By:   /s/ Olse Yu
Name: Olse Yu
Title:  Attorney

NATWEST PENSION TRUSTEE LIMITED AS TRUSTEE FOR THE NATWEST GROUP PENSION FUND (AA SECTION),

as Lender

By:   /s/ Lisa Shaw
Name: Lisa Shaw
Title:  Attorney
By:   /s/ Olse Yu
Name: Olse Yu
Title:  Attorney

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

RAYMOND JAMES BANK,

as Lender

By:   /s/ Robert F. Moyle
Name: Robert F. Moyle
Title: Managing Director

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

ROYAL BANK OF CANADA,

as Lender

By:   /s/ Jason S. York
Name: Jason S. York
Title: Authorized Signatory

 

SIGNATURE PAGE TO SIXTH AMENDMENT TO THE CTA AND FOURTH AMENDMENT

TO THE CSAA

Exhibit 10.82

Execution Version

SEVENTH AMENDMENT TO THE COMMON TERMS AGREEMENT AND FIFTH

AMENDMENT TO THE COMMON SECURITY AND ACCOUNT AGREEMENT

This SEVENTH AMENDMENT TO THE COMMON TERMS AGREEMENT AND FIFTH AMENDMENT TO THE COMMON SECURITY AND ACCOUNT AGREEMENT (this “Amendment”), dated as of October 23, 2024 (the “Effective Date”), is in respect of (a) the Common Terms Agreement, dated as of August 19, 2019, by and among Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Borrower”), TransCameron Pipeline, LLC (the “Guarantor”), Natixis, New York Branch, as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties (in such capacity, the “Credit Facility Agent”), each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Mizuho Bank, Ltd., as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”), as amended by that certain Consent and Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of December 28, 2020, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, that certain Second Amendment to the Common Terms Agreement and Consent to the Credit Facility Agreement, dated as of January 26, 2021, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, that certain Third Amendment to the Common Terms Agreement, First Amendment to the Common Security and Account Agreement and Consent to the Credit Facility Agreement, dated as of May 25, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, Mizuho Bank (USA), as Collateral Agent (in such capacity, the “Collateral Agent”) and Intercreditor Agent, that certain Fourth Amendment to the Common Terms Agreement and Second Amendment to the Credit Facility Agreement, dated as of October 12, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent and Intercreditor Agent, that certain Fifth Amendment to the Common Terms Agreement and Third Amendment to the Common Security and Account Agreement, dated February 27, 2023, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, Intercreditor Agent and Collateral Agent, and that certain Sixth Amendment to the Common Terms Agreement and Fourth Amendment to the Common Security and Account Agreement, dated June 30, 2023, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, Intercreditor Agent and Collateral Agent(as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”) and (b) the Common Security and Account Agreement, dated as of August 19, 2019, by and among the Borrower, the Guarantor, the Senior Creditor Group Representatives from time to time party thereto, the Intercreditor Agent, the Collateral Agent and Mizuho Bank, Ltd., as the account bank, as amended by that certain Third Amendment to the Common Terms Agreement, First Amendment to the Common Security and Account Agreement and Consent to the Credit Facility Agreement, dated as of May 25, 2022, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, the Collateral Agent and Intercreditor Agent, that certain Second Amendment to the Common Security and Account Agreement, dated as of January 9, 2023, by and among Borrower, Guarantor, the Collateral Agent and Intercreditor Agent, that certain Fifth Amendment to the Common Terms Agreement and Third Amendment to the Common Security and Account Agreement, dated February 27, 2023, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, Intercreditor Agent and Collateral Agent, and that certain Sixth Amendment


to the Common Terms Agreement and Fourth Amendment to the Common Security and Account Agreement, dated June 30, 2023, by and among Borrower, Guarantor, the Credit Facility Lenders party thereto, Credit Facility Agent, Intercreditor Agent and Collateral Agent (as so amended and as may be amended, amended and restated, modified or supplemented from time to time, the “Common Security and Account Agreement”). All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Common Terms Agreement. For all purposes of this Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.

WHEREAS, the Borrower has requested that the Credit Facility Lenders under the Credit Facility Agreement (collectively, the “Lenders” and each individually, a “Lender”), the Credit Facility Agent, the Collateral Agent and the Intercreditor Agent consent and agree to amend the Common Terms Agreement and the Common Security and Account Agreement in accordance with Section 23.15 of the Common Terms Agreement, Section 4 of the Intercreditor Agreement, Section 7.2(a)(i)(A) (Modification Approval Levels) and 12.14 (Amendments) of the Common Security and Account Agreement.

NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1. Consent and Amendments.

1.1 Consent and Amendment to Common Terms Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, each of the Lenders party hereto, the Credit Facility Agent (at the direction of Required Lenders) and the Intercreditor Agent hereby consent and agree as follows:

The definition of “Date Certain” in Section 1.3 (Definitions) of Schedule A (Common Definitions and Rules of Interpretation) to the Common Terms Agreement shall be amended and restated in its entirety as follows:

““Date Certain” means June 1, 2025.”

1.2 Administrative Amendment to Common Security and Account Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, the Collateral Agent (at the direction of the Intercreditor Agent) hereby consents and agrees to amend the Common Security and Account Agreement as follows:

““Date Certain” means June 1, 2025.”

 

2


Section 2. Effectiveness. This Amendment shall become effective as of the date hereof subject to satisfaction of the following conditions precedent:

2.1 delivery of executed counterparts of this Amendment by each of (i) the Borrower, (ii) the Guarantor, (iii) the Intercreditor Agent, (iv) the Collateral Agent, (v) the Credit Facility Agent (who constitutes the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement)) and (vi) Lenders constituting the Required Lenders under the Credit Facility Agreement;

2.2 the Intercreditor Agent and the Credit Facility Agent shall have received an updated Construction Budget and Schedule;

2.3 the Intercreditor Agent and the Credit Facility Agent shall have received a certificate from the Borrower certifying that:

(a) since the last delivery by the Independent Engineer of the monthly construction report as provided by Section 10.4 (Construction Reports) of the Common Terms Agreement, the Borrower has not become aware of any event or circumstance the occurrence of which could reasonably be expected to (i) increase the total Project Costs materially above those set forth in the Construction Budget and Schedule (as updated pursuant to Section 2.2), or (ii) have a Material Adverse Effect;

(b)

(i) the sum of (A) amounts on deposit in the Contingency Reserve Account, (B) amounts on deposit in the Construction Account, (C) amounts on deposit in the Pre-Completion Revenues Account, and (D) the amounts of any committed, but undrawn, Senior Debt Commitment available to the Borrower equals or exceeds

(ii) the amount of funds that are, as of the date hereof, reasonably required to achieve the Project Completion Date (excluding any amounts required to be funded in the Senior Facilities Debt Service Reserve Account and each other Additional Debt Service Reserve Account (if any) (or, if the Senior Facilities Debt Service Reserve Account or any such Additional Debt Service Reserve Account is not yet required to be funded, the amount that will be required to be funded therein on the first date on which such account is required to be funded)) by the Date Certain (as amended by this Amendment) (such amount in this clause (ii), the “Required Completion Amount”);

(c) the Borrower reasonably believes that Project Completion Date shall occur on or prior to the Date Certain (as amended by this Amendment).

2.4 the Borrower has delivered to the Intercreditor Agent a certification from the Independent Engineer confirming (a) that it reasonably expects the Project Completion Date to be achieved by the Date Certain (as amended by this Amendment) and (b) the Obligors have funds equal to or in excess of the Required Completion Amount.

 

3


Section 3. Representations and Warranties. Each of the Obligors hereby represents and warrants to the Lenders, Credit Facility Agent, the Collateral Agent and Intercreditor Agent that:

3.1 upon the effectiveness of the consents and amendments set forth in Section 1, no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing or will result from the consummation of the transactions contemplated by this Amendment; and

3.2 upon the effectiveness of the consents and amendments set forth in Section 1, each of the representations and warranties of the Obligors in the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents is true and correct in all material respects except (A) for those representations and warranties that are qualified by materiality, which are true and correct in all respects on and as of the date hereof (or, if stated to have been made solely as of an earlier date, as of such earlier date) and (B) for the representations and warranties set forth in Section 5.1 (Initial Representations and Warranties of the Obligors) of the Common Terms Agreement, which were made only on the Closing Date.

Section 4. Finance Document. This Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement. Each of the parties hereto agree that (i) each reference to “Common Terms Agreement” in each Finance Document, including the Intercreditor Agreement and the Common Security and Account Agreement, shall refer to the Common Terms Agreement as amended hereby and (ii) each reference to “Common Security and Account Agreement” in each Finance Document, including the Intercreditor Agreement and the Common Terms Agreement, shall refer to the Common Security and Account Agreement as amended hereby.

Section 5. Governing Law. THIS AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA.

Section 6. Headings. All headings in this Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.

Section 7. Binding Nature and Benefit; Amendment. This Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 8. Counterparts. This Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Amendment.

Section 9. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Common Terms Agreement, the Common Security and Account Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Amendment apply to any other matters.

 

4


Section 10. E-Signature. The words “execution,” “signed,” “signature,” and words of like import in this Amendment shall be deemed to include electronic signatures or electronic records, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any legal requirements, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

Section 11. Direction to Credit Facility Agent, Intercreditor Agent and Collateral Agent.

11.1 By their signature below, each of the undersigned Credit Facility Lenders (collectively constituting the Required Lenders) instructs the Credit Facility Agent to (i) execute this Amendment and (ii) direct the Intercreditor Agent to execute this Amendment.

11.2 Based on the instructions in Section 11.1, the Credit Facility Agent, constituting the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement), hereby directs the Intercreditor Agent to execute this Amendment.

11.3 The Borrower hereby confirms that the amendment contemplated in Section 1.2 is an Administrative Decision within the meaning of Schedule 2 to the Intercreditor Agreement and hereby requests that the Intercreditor Agent provide a direction to the Collateral Agent in accordance with Section 7.2(a)(i)(A) (Modification Approval Levels) and 12.14 (Amendments) of the Common Security and Account Agreement to execute this Amendment.

11.4 Based on the certification in Section 11.3, the Intercreditor Agent hereby directs the Collateral Agent to execute this Amendment.

[Remainder of the page left intentionally blank.]

 

5


IN WITNESS WHEREOF, the Parties have caused this Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as the Borrower

By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title: Chief Financial Officer

TRANSCAMERON PIPELINE, LLC,

as the Guarantor

By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title: Chief Financial Officer

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

By:   /s/ Katarina Janosikova
Name: Katarina Janosikova
Title: Director
By:   /s/ Frederic Bouley
Name: Frederic Bouley
Title: Director

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Intercreditor Agent

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title: Director

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK (USA),

as Collateral Agent

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title: Director

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

CAIXABANK S.A.,

as Lender

By:   /s/ Jesus Andese
Name: Jesus Ansede
Title:
By:   /s/ Maria Luisa Muñoz
Name: Maria Luisa Muñoz
Title:

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

National Bank of Canada,

as Lender

By:   /s/ Andrew Nguyen
Name: Andrew Nguyen
Title: Authorized Signatory
By:   /s/ John Hunt
Name: John Hunt
Title: Authorized Signatory

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MUNICH REINSURANCE AMERICA, INC.,

as Lender

By:   /s/ Oliver J. Horbelt
Name: Oliver J. Horbelt
Title: Senior Vice President and Chief Financial Officer
By:   /s/ Ganesh Narayan
Name: Ganesh Narayan
Title: Vice President & Controller

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

Goldman Sachs Bank USA,

as Lender

By:   /s/ Priyankush Goswami
Name: Priyankush Goswami
Title: Authorized Signatory

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

JPMORGAN CHASE BANK, N.A.,

as Lender

By:   /s/ Arina Mavilian
Name: Arina Mavilian
Title: Managing Director

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

KfW IPEX-Bank GmbH,

as Lender

By:   /s/ Philipp Meyer-Gohde
Name: Philipp Meyer-Gohde
Title: Vice President
By:   /s/ Erik Beste
Name: Erik Beste
Title: Associate

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

Sumitomo Mitsui Banking Corporation.

as Lender

By:   /s/ Brian T. Caldwell
Name: Brian T. Caldwell
Title: Managing Director

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

Landesbank Baden-Wuerttemberg New York Branch,

as Lender

By:   /s/ Arndt Bruns
Name: Arndt Bruns
Title: Director
By:   /s/ Andre Sorokin
Name: Andre Sorokin
Title: Associate

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

BANK OF AMERICA, N.A.,

as Lender

By:   /s/ Ronald E. McKaig
Name: Ronald E. McKaig
Title: Managing Director

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

[STWD 2021-SIF1, Ltd.],

as Lender

By:   /s/ Haig Najarian
Name: Haig Najarian
Title: Authorized Signatory

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

[STWD 2021-SIF2, Ltd.],

as Lender

By:   /s/ Haig Najarian
Name: Haig Najarian
Title: Authorized Signatory

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

[STWD 2024-SIF3, Ltd.],

as Lender

By:   /s/ Haig Najarian
Name: Haig Najarian
Title: Authorized Signatory

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

THE BANK OF NOVA SCOTIA, HOUSTON BRANCH,

as Lender

By:   /s/ Joe Lattanzi
Name: Joe Lattanzi
Title: Managing Director

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Lender

By:   /s/ David B Martens
Name: David B Martens
Title: Managing Director
By:   /s/ John Sickler
Name: John Sickler
Title: Director

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

MIZUHO BANK, LTD.,

as Lender

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title: Director

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA


Acknowledged and agreed as of the first date set forth above.

RAYMOND JAMES BANK,

as Lender

By:   /s/ Robert F. Moyle
Name: Robert F. Moyle
Title: Managing Director

 

SIGNATURE PAGE TO SEVENTH AMENDMENT TO THE CTA AND FIFTH

AMENDMENT TO THE CSAA

Exhibit 10.83

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

 

 

Execution Version

VENTURE GLOBAL CALCASIEU PASS, LLC,

as Issuer,

and

TRANSCAMERON PIPELINE, LLC,

as the Guarantor,

AND EACH GUARANTOR THAT MAY BECOME PARTY HERETO

 

 

INDENTURE

Dated as of August 5, 2021

 

 

The Bank of New York Mellon Trust Company, N.A.,

as Trustee

 

 


TABLE OF CONTENTS

 

Article 1 DEFINITIONS AND INCORPORATION BY REFERENCE

     1  

Section 1.01

 

Definitions

     1  

Section 1.02

 

Other Definitions

     41  

Section 1.03

 

Rules of Construction

     43  
Article 2 THE NOTES      44  

Section 2.01

 

Form and Dating

     44  

Section 2.02

 

Execution and Authentication

     46  

Section 2.03

 

Registrar and Paying Agent; Depositary

     46  

Section 2.04

 

Paying Agent to Hold Money in Trust

     47  

Section 2.05

 

Holder Lists

     47  

Section 2.06

 

Transfer and Exchange

     47  

Section 2.07

 

Replacement Notes

     60  

Section 2.08

 

Outstanding Notes

     61  

Section 2.09

 

Treasury Notes

     61  

Section 2.10

 

Temporary Notes

     61  

Section 2.11

 

Cancellation

     61  

Section 2.12

 

Defaulted Interest

     62  
Article 3 REDEMPTION AND OFFERS TO PURCHASE NOTES      62  

Section 3.01

 

Notices to Trustee

     62  

Section 3.02

 

Selection of Notes to Be Redeemed

     62  

Section 3.03

 

Notice of Redemption

     63  

Section 3.04

 

Effect of Notice of Redemption

     64  

Section 3.05

 

Deposit of Redemption or Purchase Price

     64  

Section 3.06

 

Notes Redeemed in Part

     65  

Section 3.07

 

Optional Redemption

     65  

Section 3.08

 

Open Market Purchases; No Mandatory Redemption or Sinking Fund

     66  

Section 3.09

 

Offer to Purchase by Application of Excess Proceeds, Excess Loss Proceeds, PLD Excess Proceeds and LNG SPA Mandatory Offer Amount

     67  
Article 4 COVENANTS      69  

Section 4.01

 

Payment of Notes

     69  

Section 4.02

 

Maintenance of Office or Agency

     70  

Section 4.03

 

Reporting Requirements

     70  

Section 4.04

 

Compliance Certificate

     71  

Section 4.05

 

Taxes

     71  

Section 4.06

 

Restricted Payments

     71  

Section 4.07

 

Dividend and Other Payment Restrictions Affecting Subsidiaries

     74  

Section 4.08

 

Limitation on Indebtedness

     75  

Section 4.09

 

Incurrence of Senior Debt

     78  

Section 4.10

 

Permitted Development Expenditures

     82  

 

i


Section 4.11

 

Expansions

     82  

Section 4.12

 

Asset Sales

     85  

Section 4.13

 

Transactions with Affiliates

     87  

Section 4.14

 

Liens

     88  

Section 4.15

 

Nature of Business

     88  

Section 4.16

 

Maintenance of Existence

     89  

Section 4.17

 

Change of Control

     89  

Section 4.18

 

Limitation on Investments and Loans

     91  

Section 4.19

 

Events of Loss

     91  

Section 4.20

 

Performance Liquidated Damages

     92  

Section 4.21

 

LNG SPA Mandatory Offer

     93  

Section 4.22

 

Access

     96  

Section 4.23

 

Insurance

     96  

Section 4.24

 

Compliance with Law

     97  

Section 4.25

 

Limitation on Guarantees

     97  

Section 4.26

 

Material Project Agreements

     97  

Section 4.27

 

Customary Lifting and Balancing Arrangements

     98  

Section 4.28

 

Sharing of Project Facilities

     98  

Section 4.29

 

LNG SPA Maintenance

     100  

Section 4.30

 

Amendment of LNG SPAs

     102  

Section 4.31

 

Sale of Supplemental Quantities

     102  

Section 4.32

 

Sale of Pre-Commercial Quantities

     102  

Section 4.33

 

Export Authorizations

     103  

Section 4.34

 

FERC Order

     103  

Section 4.35

 

Hedging Arrangements

     103  

Section 4.36

 

Project Construction; Maintenance of Properties

     103  

Section 4.37

 

Maintenance of Liens

     103  

Section 4.38

 

Credit Rating Agencies

     104  

Section 4.39

 

Additional Note Guarantees

     104  

Section 4.40

 

Designation of Restricted and Unrestricted Subsidiaries

     104  

Section 4.41

 

Separateness

     105  

Section 4.42

 

Use of Proceeds

     107  

Section 4.43

 

Payments for Consents

     107  

Section 4.44

 

Application of Covenants to TCP and its Subsidiaries Following a Permitted Pipeline Sale

     107  

Section 4.45

 

Changes in Covenants when Notes Rated Investment Grade

     107  
Article 5 SUCCESSORS      109  

Section 5.01

 

Merger, Liquidation, Sale of All Assets

     109  

Section 5.02

 

Successor Corporation Substituted

     110  
Article 6 DEFAULTS AND REMEDIES      110  

Section 6.01

 

Events of Default

     110  

Section 6.02

 

Declaration of Declared Event of Default

     114  

Section 6.03

 

Acceleration

     114  

Section 6.04

 

Waivers of Defaults and Acceleration

     114  

 

ii


Section 6.05

 

Remedies of Holders

     115  

Section 6.06

 

Control by Majority

     117  

Section 6.07

 

Rights of Holders to Receive Payment

     117  

Section 6.08

 

Collection Suit by Trustee

     117  

Section 6.09

 

Trustee May File Proofs of Claim

     117  

Section 6.10

 

Priorities

     118  

Section 6.11

 

Undertaking for Costs

     118  
Article 7 TRUSTEE      119  

Section 7.01

 

Duties of Trustee

     119  

Section 7.02

 

Rights of Trustee

     120  

Section 7.03

 

Individual Rights of Trustee

     122  

Section 7.04

 

Trustee’s Disclaimer

     122  

Section 7.05

 

Notice of Defaults

     122  

Section 7.06

 

[Reserved]

     123  

Section 7.07

 

Compensation and Indemnity

     123  

Section 7.08

 

Replacement of Trustee

     124  

Section 7.09

 

Successor Trustee by Merger, etc.

     125  

Section 7.10

 

Eligibility; Disqualification

     125  

Section 7.11

 

Authorization to Enter Into Accession Agreement

     125  

Section 7.12

 

Trustee Protective Provisions

     125  
Article 8 LEGAL DEFEASANCE AND COVENANT DEFEASANCE      125  

Section 8.01

 

Option to Effect Legal Defeasance or Covenant Defeasance

     125  

Section 8.02

 

Legal Defeasance and Discharge

     126  

Section 8.03

 

Covenant Defeasance

     126  

Section 8.04

 

Conditions to Legal or Covenant Defeasance

     127  

Section 8.05

 

Deposited Money and Government Securities to be Held in Trust; Other Miscellaneous Provisions

     128  

Section 8.06

 

Repayment to Company

     129  

Section 8.07

 

Reinstatement

     129  
Article 9 AMENDMENT, SUPPLEMENT AND WAIVER      129  

Section 9.01

 

Without Consent of Holders

     129  

Section 9.02

 

With Consent of Holders

     131  

Section 9.03

 

Decisions under Other Finance Documents

     132  

Section 9.04

 

[Reserved]

     134  

Section 9.05

 

Revocation and Effect of Consents

     134  

Section 9.06

 

Notation on or Exchange of Notes

     134  

Section 9.07

 

Trustee to Sign Amendments, etc.

     134  
Article 10 COLLATERAL AND SECURITY      134  

Section 10.01

 

Security

     134  

Section 10.02

 

Security Documents

     135  

Section 10.03

 

Collateral

     135  

 

iii


Section 10.04  

Release of Security Interests

     135  
Section 10.05  

Release of Collateral

     136  
Section 10.06  

Termination of Security Interest

     136  
Article 11 NOTE GUARANTEES      136  
Section 11.01  

Note Guarantee

     136  
Section 11.02  

Limitation on Guarantor Liability

     137  
Section 11.03  

Execution and Delivery of Note Guarantee Notation

     138  
Section 11.04  

Guarantors May Consolidate, etc., on Certain Terms

     138  
Section 11.05  

Releases

     140  
Article 12 SATISFACTION AND DISCHARGE      141  
Section 12.01  

Satisfaction and Discharge

     141  
Section 12.02  

Application of Trust Money

     142  
Article 13 MISCELLANEOUS      142  
Section 13.01  

[Reserved]

     142  
Section 13.02  

Notices

     142  
Section 13.03  

[Reserved]

     144  
Section 13.04  

Certificate and Opinion as to Conditions Precedent

     144  
Section 13.05  

Statements Required in Certificate or Opinion

     145  
Section 13.06  

Rules by Trustee and Agents

     145  

Section 13.07

 

No Personal Liability of Directors, Officers, Employees and Stockholders

     145  
Section 13.08  

Governing Law; Waiver of Jury Trial; Jurisdiction

     145  
Section 13.09  

No Adverse Interpretation of Other Agreements

     146  
Section 13.10  

Successors

     146  
Section 13.11  

Severability

     146  
Section 13.12  

Execution; Counterpart Originals

     147  
Section 13.13  

Trustee’s Receipt of Funds to the Extent not Required to be Applied to Payment of the Notes

     147  
Section 13.14  

Table of Contents, Headings, etc.

     147  

 

iv


EXHIBITS

 

Exhibit A-1   FORM OF 2029 NOTE
Exhibit A-2   FORM OF 2029 REGULATION S TEMPORARY GLOBAL NOTE
Exhibit A-3   FORM OF 2031 NOTE
Exhibit A-4   FORM OF 2031 REGULATION S TEMPORARY GLOBAL NOTE
Exhibit B   FORM OF CERTIFICATE OF TRANSFER
Exhibit C   FORM OF CERTIFICATE OF EXCHANGE
Exhibit D   FORM OF NOTATION OF GUARANTEE
Exhibit E   FORM OF SUPPLEMENTAL INDENTURE
Exhibit F   ADDITIONAL NOTES AND SUPPLEMENTAL INDENTURES FOR ADDITIONAL NOTES
Exhibit G   FORM OF CERTIFICATE OF ACQUIRING INSTITUTIONAL ACCREDITED INVESTOR
Exhibit H   FORM OF NET SHORT REPRESENTATION
Exhibit I   COMMON SECURITY AND ACCOUNT AGREEMENT

 

v


INDENTURE dated as of August 5, 2021 among Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Company”), TransCameron Pipeline, LLC (“TCP”) and any other Guarantors (as defined herein) that may become a party hereto from time to time, and The Bank of New York Mellon Trust Company, N.A., as Trustee.

The Company, the Guarantors and the Trustee agree as follows for the benefit of each other and for the equal and ratable benefit of the Holders (as defined herein) of Notes (as defined herein).

ARTICLE 1

DEFINITIONS AND INCORPORATION

BY REFERENCE

Section 1.01 Definitions.

2029 Notes” means the $1,250,000,000 aggregate principal amount of the Company’s 3.875% senior secured notes due 2029, issued under this Indenture on the date hereof.

2031 Notes” means the $1,250,000,000 aggregate principal amount of the Company’s 4.125% senior secured notes due 2031, issued under this Indenture on the date hereof.

Abandonment” has the meaning given in Schedule A of the CSAA.

Acceptable Bank” has the meaning given in Schedule A of the CSAA.

Acceptable Debt Service Reserve LC” has the meaning given in Schedule A of the CSAA.

Account Bank” has the meaning given in Schedule A of the CSAA.

ACQ” means annual contract quantity as set forth in the applicable LNG SPA.

Additional Debt Service Reserve Account(s)” has the meaning given in Schedule A of the CSAA.

Additional Notes” means Notes (other than the Initial Notes) issued under this Indenture in accordance with Section 2.01(d) and Exhibit F.

Additional Proceeds Prepayment Account” has the meaning given in Schedule A of the CSAA.

Additional Qualifying LNG SPA” means any LNG SPA that meets each of the following conditions but does not meet the conditions to be a Qualifying LNG SPA:

 

  (a)

such LNG SPA has a term of at least three (3) years;

 

  (b)

such LNG SPA either has “free on board” or “delivered ex ship” terms;

 

  (c)

such LNG SPA is entered into with a counterparty that either (i) has an Investment Grade rating (or has its obligations guaranteed by an entity that has an Investment Grade rating) or (ii) has consolidated net tangible assets of at least $3 billion for each MTPA or portion thereof (or has its obligations guaranteed by an entity that has such consolidated net tangible assets); and

 

1


  (d)

no Material Adverse Effect occurs, or could reasonably be expected to occur, as a result of entering into such LNG SPA, taken as a whole;

provided that, no Additional Qualifying LNG SPA shall constitute a Qualifying Indenture LNG SPA unless the Company or its Restricted Subsidiaries have other Qualifying LNG SPAs for at least 8.0 MTPA of ACQ.

Administrative Service Agreements” has the meaning given in Schedule A of the CSAA.

Advance” has the meaning given in Schedule A of the CSAA.

Affiliate” has the meaning given in Schedule A of the CSAA.

Agent” means any Registrar, co-registrar, Paying Agent or additional paying agent.

Applicable Law” means, except as the context may otherwise require, all applicable laws (including common law), rules, regulations, ordinances, judgments, decrees, injunctions, writs and orders of any Governmental Authority.

Applicable Procedures” means, with respect to any transfer or exchange of or for beneficial interests in any Global Note, the rules and procedures of the Depositary, Euroclear and Clearstream that apply to such transfer or exchange.

Approved Owner” has the meaning given in Schedule A of the CSAA.

Asset Sale” means:

 

  (a)

the sale, lease, conveyance or other disposition of any assets or rights; provided that, except in connection with a Permitted Pipeline Sale, the sale, lease, conveyance or other disposition of all or substantially all of the assets of the Company and its Restricted Subsidiaries, taken as a whole, or of TCP and its Restricted Subsidiaries, taken as a whole, will be governed by the provisions of Section 5.01 and not by the provisions of Section 4.12; and

 

  (b)

the issuance of Equity Interests in TCP or any of the Company’s or TCP’s Restricted Subsidiaries or the sale of Equity Interests in TCP or any of the Company’s or TCP’s Subsidiaries.

Notwithstanding the preceding, none of the following items will be deemed to be an Asset Sale:

 

  (i)

any single transaction or series of related transactions that involves assets having a Fair Market Value of less than $50,000,000;

 

2


  (ii)

a transfer of assets between or among the Company, TCP and/or its respective Restricted Subsidiaries; provided that, this clause (ii) shall not apply to any transfer of assets by the Company and/or its Restricted Subsidiaries, on the one hand, to TCP and/or its Subsidiaries, on the other hand, made following or in contemplation of a Permitted Pipeline Sale;

 

  (iii)

dispositions in compliance with any applicable court or governmental order;

 

  (iv)

an issuance of Equity Interests by a Restricted Subsidiary to the Company or TCP or to any other Restricted Subsidiary; provided that, this clause (iv) shall not apply to an issuance of Equity Interests by a Restricted Subsidiary of the Company to TCP and/or its Subsidiaries entered into following or in contemplation of a Permitted Pipeline Sale;

 

  (v)

the sale, lease or other disposition of (A) products, services, inventory or accounts receivable in the ordinary course of business or (B) obsolete, superfluous or replaced assets, or assets that are not, or cease to be, necessary for the construction and operation of the Development;

 

  (vi)

the sale, transfer or other disposition of cash or Authorized Investments;

 

  (vii)

the settlement, release, waiver or surrender of contract, tort or other claims in the ordinary course of business or a grant of a Lien not prohibited by this Indenture;

 

  (viii)

a Restricted Payment made in accordance with this Indenture, a Permitted Investment or a Permitted Payment;

 

  (ix)

the sale or other disposition of LNG (or other commercial products);

 

  (x)

the sale of Gas in the ordinary course of business;

 

  (xi)

the sale or other disposition of Permitted Investments;

 

  (xii)

the sale of LNG, liquefaction and other services in the ordinary course of business;

 

  (xiii)

the transfer or novation of Permitted Hedging Instruments in accordance with the Finance Documents;

 

  (xiv)

conveyance of gas interconnection or metering facilities to gas transmission companies and conveyance of electricity substations to electricity providers pursuant to its electricity purchase arrangements for operating the Project Facilities;

 

  (xv)

any transaction or series of transactions permitted by Section 4.27 or Section 4.28;

 

3


  (xvi)

any single transaction or series of related transactions pursuant to the terms of an agreement existing on the Notes Issue Date; and

 

  (xvii)

the sale, transfer, conveyance or other disposition of carbon credits, tax credits or similar attributes or credits.

Authorized Investments” has the meaning given in Schedule A of the CSAA.

Authorized Officer” has the meaning given in Schedule A of the CSAA.

Bankruptcy” has the meaning given in Schedule A of the CSAA.

Bankruptcy Code” has the meaning given in Schedule A of the CSAA.

Bankruptcy Law” means the Bankruptcy Code and any other state or federal insolvency, reorganization, moratorium or similar law for the relief of debtors.

Base Committed Quantity” means eight (8) MTPA, being the aggregate ACQ under the Qualifying LNG SPAs as at the Notes Issue Date; provided, in each case, that following the full payment of the required amount upon any LNG SPA Mandatory Prepayment and/or LNG SPA Mandatory Offer, the Base Committed Quantity will be equal to the aggregate ACQ under the Qualifying LNG SPAs used to calculate the amount of Senior Debt that the Company is not required to repay upon an Indenture LNG SPA Prepayment Event under Section 4.21; provided, further, that upon incurrence of any Expansion Senior Debt, the Base Committed Quantity shall be adjusted to take into account the aggregate ACQ under the Qualifying LNG SPAs that have been taken into account for debt sizing purposes in order to incur such Expansion Senior Debt, with such adjustment becoming effective at financial close of such Expansion Senior Debt.

beneficial owner” has the meaning assigned to such term in Rule 13d-3 and Rule 13d-5 under the Exchange Act, except that in calculating the beneficial ownership of any particular “person” (as that term is used in Section 13(d)(3) of the Exchange Act), such “person” will be deemed to have beneficial ownership of all securities that such “person” has the right to acquire by conversion or exercise of other securities, whether such right is currently exercisable or is exercisable only after the passage of time. The terms “beneficially owns” and “beneficially owned” have a corresponding meaning.

BP” means BP Gas Marketing Limited.

BHGE” means Baker Hughes Energy Services LLC (f/k/a GE Oil & Gas, LLC).

Board of Directors” means:

 

  (a)

with respect to a corporation, the board of directors of the corporation or any committee thereof duly authorized to act on behalf of such board;

 

  (b)

with respect to a partnership, the board of directors, members or managers of the general partner of the partnership;

 

4


  (c)

with respect to a limited liability company, the managing member or members or managers or any controlling committee of managing members or managers thereof; and

 

  (d)

with respect to any other Person, the board, managers or committee of such Person serving a similar function.

Business Day” has the meaning given in Schedule A of the CSAA.

Business Interruption Insurance Proceeds” has the meaning given in Schedule A of the CSAA.

Calculation Date” means the last day of the month immediately preceding the date on which a Restricted Payment is made.

Calculation Period” means, on any Calculation Date, for purposes of calculating Historical DSCR or Projected Fixed DSCR in connection with a Restricted Payment:

 

  (a)

in the case of Historical DSCR, the period commencing 12 months prior to, and ending on, the applicable Calculation Date; provided that, prior to the first anniversary of Facility Substantial Completion, the Calculation Period shall mean the period beginning on the first day of the first full month following Facility Substantial Completion, and ending on the Calculation Date; and

 

  (b)

in the case of Projected Fixed DSCR, the period commencing on the first day after the applicable Calculation Date through the following 12 month period (with such ratio being calculated on a pro forma basis giving effect to such Restricted Payment).

Capital Stock” means:

 

  (a)

in the case of a corporation, corporate stock or shares in the capital of such corporation;

 

  (b)

in the case of an association or business entity, any and all shares, interests, participations, rights or other equivalents (however designated) of corporate stock;

 

  (c)

in the case of a partnership or limited liability company, partnership interests (whether general or limited or membership interests (however designated)); and

 

  (d)

any other interest or participation that confers on a Person the right to receive a share of the profits and losses of, or distributions of assets of, the issuing Person;

provided that any instrument evidencing Indebtedness convertible or exchangeable into Capital Stock, whether or not such instrument includes any right of participation with Capital Stock, shall not be deemed to be Capital Stock unless and until such instrument is so converted or exchanged.

 

5


Cash Flow” means, with respect to any period, all funds received or, as applicable in the relevant context, projected to be received by the Obligors during such period, without duplication, including:

 

  (a)

amounts received by the Company under the LNG SPAs (including in respect of Supplemental Quantities sold by the Company as permitted under Section 8.4 of the Common Terms Agreement and in respect of quantities of LNG sold by the Company prior to the Commercial Operation Date as permitted under Section 8.5 of the Common Terms Agreement;

 

  (b)

earnings on funds held in the Secured Accounts (excluding interest and investment earnings that accrue on the amounts on deposit in any of the Senior Facilities Debt Service Reserve Account or any account established to prefund interest on any Senior Debt), if any, in any case, that are not transferred to the Revenue Account pursuant to the CSAA;

 

  (c)

any amounts deposited in the Insurance/Condemnation Proceeds Account to the extent applied to the payment of Operation and Maintenance Expenses or Project Costs in accordance with Article 5 of the CSAA;

 

  (d)

all cash paid to the Obligors during such period as Business Interruption Insurance Proceeds;

 

  (e)

proceeds from the transfer, sale or disposition of assets or rights of the Obligors in the ordinary course of business in accordance with Section 12.17 of the Common Terms Agreement (other than as set forth in sub-clause (vi) below) to the extent such proceeds have been or will be used to pay Operation and Maintenance Expenses;

 

  (f)

amounts paid to each Obligor under any Material Project Agreement;

 

  (g)

amounts received by each Obligor under Permitted Hedging Instruments other than in respect of interest rates;

 

  (h)

solely with respect to the calculation of Historical DSCR, (I) all cash paid to the Company and/or its Restricted Subsidiaries during the applicable period from any direct or indirect owner of the Company and/or its Restricted Subsidiaries by way of equity contribution or Subordinated Debt (as permitted pursuant to the terms of the Senior Debt Instruments then in effect) and (II) in the case of the first Restricted Payment made after the expiry or termination of any period during which the making of Restricted Payments has been restricted, any cash then on deposit in the Secured Accounts (without double counting any other amounts of Cash Flow taken into account in the calculation of the Historical DSCR);

 

  (i)

with respect to the calculation of Projected Fixed DSCR for any purpose other than such calculation under Section 11 of the Common Terms Agreement, and for any period, any cash projected to be on deposit in the Secured Accounts at the commencement of such period as a result of a restriction on the making of Restricted Payments applicable prior to such period (without double counting any other amounts of Cash Flow taken into account in the calculation of the Projected Fixed DSCR); and

 

6


  (j)

with respect to the calculation of Projected Fixed DSCR for any purpose other than such calculation under Section 4.06(a)(2), any cash projected to be on deposit in the Secured Accounts at the commencement of such period as a result of a restriction on making of Restricted Payments applicable prior to such period (without double counting any other amounts of Cash Flow taken into account in the calculation of the Projected Fixed DSCR);

but excluding, in each case:

 

  (i)

all amounts required to be deposited in the Insurance/Condemnation Proceeds Account used to reimburse Equity Funding;

 

  (ii)

all proceeds of Senior Debt that are used to reimburse Drawstop Equity Contributions;

 

  (iii)

proceeds of the final Advance on the Project Completion Date;

 

  (iv)

the proceeds of the Project Completion Date Distribution;

 

  (v)

proceeds of third-party liability insurance;

 

  (vi)

proceeds from the sale, lease or other disposition of obsolete, superfluous or replaced assets, or assets that are not, or cease to be, necessary for the construction and operation of the Development, as described in sub-clause (B) of clause (v) under the definition of “Asset Sale” hereunder and dispositions of Project Property if an Obligor replaces such Project Property within 180 days following such disposition or has obtained a commitment to replace such Project Property within 180 days following such disposition and replaces such Project Property within 270 days following such disposition;

 

  (vii)

proceeds of Senior Debt and other Indebtedness (and corresponding amounts received by the Obligors pursuant to any guarantees) permitted by Section 4.08 other than amounts received under Permitted Hedging Instruments included under clause (g) above;

 

  (viii)

except as provided in clause (h) above, Equity Funding received from the Sponsor or any direct or indirect holders of equity interests of the Company; and

 

  (ix)

any cash deposited into the Additional Proceeds Prepayment Account.

 

7


Cash Flow Available for Debt Service” means, for any Calculation Period, the amount equal to (a) Cash Flow for such period minus (b) Operation and Maintenance Expenses, for such period; provided that Operation and Maintenance Expenses included in the calculation of Historical DSCR and Projected Fixed DSCR will exclude (i) that portion of Operation and Maintenance Expenses arising prior to the Project Completion Date that are Project Costs and, in the case of an Expansion, arising prior to the completion date of such Expansion and that are pre-completion project costs of such Expansion, (ii) that portion of Operation and Maintenance Expenses that are Required Capital Expenditures and (iii) Operation and Maintenance Expenses arising from and after the Project Completion Date or the completion date of an Expansion, as applicable, relating to expenditure on items that were, as of the Project Completion Date or the completion date of such Expansion, as applicable, outstanding or punch list items under the Material Construction Contracts (and for which sufficient reserves are on deposit in the Completion Reserve Account), or Expansion engineering, procurement and/or construction contract, as applicable, that are paid out of Senior Debt or Equity Funding.

Catastrophic Casualty Event” means any Event of Loss where Insurance Proceeds or Condemnation Proceeds are received in an aggregate amount for a single loss or related series of losses exceeding $500,000,000.

CB&I” means CB&I LLC.

Change of Control” means (a) at any time prior to the Project Completion Date, the Sponsor, any person who is a shareholder (including, for the avoidance of doubt, Falcon LNG LLC and any of its affiliates) of the Sponsor as of the Notes Issue Date, any Approved Owner or any of their respective Affiliates, collectively, shall fail to own, directly or indirectly in the aggregate, more than 50% of the equity ownership interests in the Company and TCP, or control, directly or indirectly, more than 50% of the aggregate ordinary voting power of the Company and TCP, (b) on or following the Project Completion Date, (i) the Sponsor, any Approved Owner or any of their respective Affiliates, collectively, or (ii) a Qualified Owner shall fail to control, directly or indirectly, more than 50% of the aggregate ordinary voting power in the Company and TCP; or (c) at any time, the Pledgor shall cease to directly maintain 100% of the voting and economic interests in the Company or TCP; provided that, (A) a Permitted Pipeline Sale shall not be a Change of Control and (B) from and after the occurrence of any Permitted Pipeline Sale, any references to TCP in the foregoing shall no longer apply.

Change of Control Triggering Event” means the occurrence of a Change of Control; provided that, on and following the Project Completion Date, a Change of Control shall not be deemed to have occurred if the Company shall have received letters from any two Recognized Credit Rating Agencies (or if only one Recognized Credit Rating Agency is then rating the Notes of such series, the Company shall have received a letter from that Recognized Credit Rating Agency) to the effect that the Recognized Credit Rating Agency has considered the contemplated Change of Control and that, if such event occurs, there would be no downgrading in the rating such Recognized Credit Rating Agency would provide for the Notes of such series as of the date of such event.

Clearstream” means Clearstream Banking, S.A.

Closing Date Equity Funding” has the meaning given in Schedule A of the CSAA.

 

8


Collateral” means any property right or interest subject to a Security Interest.

Collateral Agent” means Mizuho Bank (USA) as the trustee named under the CSAA as collateral agent for the Secured Parties.

Commercial Operation Date” has the meaning given in the applicable LNG SPA.

Common Terms Agreement” has the meaning given in Schedule A of the CSAA.

Company” has the meaning set forth in the recitals hereto.

Completion Reserve Account” means the account described in Section 4.3(a)(xiv) (Accounts) of the CSAA.

Condemnation Proceeds” has the meaning given in Schedule A of the CSAA.

Constitutional Documents” means certificates of formation, limited liability company agreements, partnership agreements, certificates of incorporation, bylaws or any similar entity organizational or constitutive document.

Construction Account” has the meaning given in Schedule A of the CSAA.

Construction Contractors” means the EPC Contractor, WHC, BHGE, UOP, Weeks Marine and CB&I.

Contingency Reserve Account” has the meaning given in Schedule A of the CSAA.

Continuing” (including, with its corresponding meaning, the terms “Continuance” and “Continuation”) means:

 

  (a)

with respect to any Loan Facility Declared Default, Declared Event of Default or other comparable event of default or termination event under any other Senior Debt Instrument or Permitted Hedging Instrument, that such event of default or termination event has occurred without the need for declaration, or been declared by required Senior Creditor action, in each case in conformity with the requirements of the Common Terms Agreement or such other Senior Debt Instrument or Permitted Hedging Instrument, as the case may be, and no Cessation Notice or similar notice shall have been given with respect thereto;

 

  (b)

with respect to any Unmatured Loan Facility Event of Default, Unmatured Event of Default or other unmatured default or termination event under any other Senior Debt Instrument or Permitted Hedging Instrument, that such unmatured default or termination event has occurred and has not been waived or cured; and

 

  (c)

with respect to any Loan Facility Event of Default, Indenture Event of Default or other event of default or termination event under any other Senior Debt Instrument or Permitted Hedging Instrument, that such event of default or termination event has occurred and has not been declared, waived or cured.

 

9


Control Agreements” has the meaning given in Schedule A of the CSAA.

Corporate Trust Office” means the office of the Trustee at which at any particular time its corporate trust business in Pittsburgh, Pennsylvania shall be principally administered, which office as of the date of this instrument is located at the address specified in Section 13.02, except that with respect to presentation of Notes for payment or for registration of transfer or exchange, such term shall mean the office or agency of the Trustee at which at any particular time its corporate agency business shall be conducted, which office at the date of this instrument is located at 601 Travis Street, 16th Floor, Houston, Texas 77002; Attention: Corporate Trust Administration, or, in the case of any of such offices or agency, such other address as the Trustee may designate from time to time by notice to the Company.

Covered Modification” means any modification, consent or waiver under any Finance Document requiring the vote of the Trustee as a Senior Creditor Group Representative, including, for the avoidance of doubt, those set forth in Section 7.2(a), Section 7.2(b), and Section 7.2(c) of the CSAA.

Credit Facilities Closing Date” means the date on which the conditions precedent set forth in Section 4.1 (Conditions to Closing Date and Initial Advance) and Section 4.2 (Conditions to Each Advance) of the Common Terms Agreement have been satisfied or waived.

Credit Facility Agent” means Natixis, New York Branch, as facility agent under the Credit Facility Agreement.

Credit Facility Agreement” is the Credit Facility Agreement, dated as of the Credit Facilities Closing Date, by and among Company as the borrower, TCP, the Credit Facility Lender Parties party thereto from time to time, the Credit Facility Agent and, solely for purposes of Section 3.06 thereof, the Collateral Agent.

Credit Facility Lender Parties” means the Credit Facility Lenders and the Issuing Banks under the Credit Facility Agreement.

“Credit Facility Lenders” means the “Lenders” under the Credit Facility Agreement.

CSAA” means the Common Security and Account Agreement, dated as of August 19, 2019, among the Company, TCP, each Senior Creditor Group Representative on its own behalf and on behalf of the relevant Senior Creditor Group party thereto from time to time, the Intercreditor Agent, the Collateral Agent and the Account Bank. For purposes of this Indenture, references to the CSAA refer to the CSAA, attached as Exhibit I hereto, as in effect on the Notes Issue Date.

Custodian” means the Trustee, as custodian with respect to the Notes in global form, or any successor entity thereto.

Date Certain” has the meaning given in Schedule A of the CSAA.

Debt Service” has the meaning given in Schedule A of the CSAA.

 

10


Debt Service Reserve Account” has the meaning given in Schedule A of the CSAA.

Decision” has the meaning given in Schedule A of the CSAA.

Definitive Note” means a certificated Note registered in the name of the Holder thereof, issued in accordance with Section 2.06, and, in the case of Initial Notes, substantially in the form of Exhibit A-1 and Exhibit A-3 except that such Note shall not bear the Global Note Legend and shall not have the “Schedule of Exchanges of Interests in the Global Note” attached thereto.

Depositary” means a common depositary for Euroclear and Clearstream.

Derivative Instrument” with respect to a Person, means any contract, instrument or other right to receive payment or delivery of cash or other assets to which such Person or any Affiliate of such Person that is acting in concert with such Person in connection with such Person’s investment in the Notes (other than a Screened Affiliate) is a party (whether or not requiring further performance by such Person), the value and/or cash flows of which (or any material portion thereof) are materially affected by the value and/or performance of the Notes and/or the creditworthiness of the Company.

Development” means the financing, development, engineering, acquisition, ownership, occupation, construction, equipping, testing, commissioning, completing, debottlenecking, insurance, repair, operation, maintenance and use of the Project Facilities and the purchase, transportation and sale of Gas and the production, storage and sale of LNG, the export of LNG from the Project Facilities, the transportation of Gas to the Project Facilities by an Obligor or third parties, and the sale of other services or other products or by-products of the Project Facilities and all activities incidental thereto (including, without limitation, carbon capture and sequestration), in each case in accordance with the Transaction Documents. “Develop” and “Developed” shall have corresponding meanings.

Development Expenditures” means, for any period, the aggregate amount of all expenditures of the Obligors payable during such period that, in accordance with GAAP, are or should be included in “purchase of property, plant and equipment” or similar items reflected in the consolidated statement of cash flows of the Obligors.

Direct Agreements” has the meaning given in Schedule A of the CSAA.

Disqualified Stock” means any Capital Stock that, by its terms (or by the terms of any security into which it is convertible, or for which it is exchangeable, in each case, at the option of the holder of the Capital Stock), or upon the happening of any event, matures or is mandatorily redeemable, pursuant to a sinking fund obligation or otherwise, or redeemable at the option of the holder of the Capital Stock, in whole or in part, on or prior to the date that is 91 days after the date on which the Notes mature. Notwithstanding the preceding sentence, any Capital Stock that would constitute Disqualified Stock solely because the holders of the Capital Stock have the right to require the Company or TCP to repurchase such Capital Stock upon the occurrence of a change of control or an asset sale will not constitute Disqualified Stock if the terms of such Capital Stock provide that the Company or TCP, as applicable, may not repurchase or redeem any such Capital Stock pursuant to such provisions unless such repurchase or redemption complies with the requirements of Section 4.06. The amount of Disqualified Stock deemed to be outstanding at any time for purposes of this Indenture will be the maximum amount that the Obligors may become obligated to pay upon the maturity of, or pursuant to any mandatory redemption provisions of, such Disqualified Stock, exclusive of accrued dividends.

 

11


Domestic Subsidiary” means any Restricted Subsidiary of the Company or TCP that was formed under the laws of the United States or any state of the United States or the District of Columbia or that guarantees or otherwise provides direct credit support for any Indebtedness of the Company or TCP.

Drawstop Equity Contributions” has the meaning given in Schedule A of the CSAA.

Edison” means Edison S.p.A.

Electronic Means” means the following communications methods: e-mail, facsimile transmission, secure electronic transmission containing applicable authorization codes, passwords and/or authentication keys issued by the Trustee, or another method or system specified by the Trustee as available for use in connection with its services hereunder.

EPC Contract” has the meaning given in Schedule A of the CSAA.

EPC Contract Guaranty” has the meaning given in Schedule A of the CSAA.

EPC Contractor” means Kiewit Louisiana Co.

Equity Funding” has the meaning given in Schedule A of the CSAA.

Equity Interests” has the meaning given in Schedule A of the CSAA.

Euroclear” means Euroclear Bank S.A./N.V.

Event of Loss” means any event that causes any Project Facilities, or any portion thereof, to be damaged, destroyed or rendered unfit for normal use for any reason whatsoever, and, in each case, shall include an Event of Taking.

Event of Taking” has the meaning given in Schedule A of the CSAA.

Excess Capacity LNG SPA” means the LNG Sales and Purchase Agreement (FOB) between the Company and Venture Global Commodities, LLC, dated as of November 14, 2018, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement, dated as of June 24, 2019, and as supplemented by Notice of CP Satisfaction Date, dated as of August 19, 2019.

Exchange Act” means the Securities Exchange Act of 1934, as amended.

Export Authorization” has the meaning given in Schedule A of the CSAA.

External LNG/CCS Assets” means one or more pipelines, trains, and related storage, loading and other ancillary infrastructure (including, without limitation, carbon capture and sequestration facilities), if any, constructed at or adjacent to the site of, the Development and is not owned by the Company or a Restricted Subsidiary.

 

12


External LNG/CCS Entity” means the entity undertaking development of External LNG/CCS Assets.

Facility Agent” has the meaning given in Schedule A of the CSAA.

Facility Agreements” has the meaning given in Schedule A of the CSAA.

Facility Debt Commitment” has the meaning given in Schedule A of the CSAA.

Facility Lenders” has the meaning given in Schedule A of the CSAA.

Facility Substantial Completion” has the meaning given to that term in the EPC Contract.

Fair Market Value” means the value that would be paid by a willing buyer to an unaffiliated willing seller in a transaction not involving distress or necessity of either party, determined in good faith by the Board of Directors, board of managers or similar body, or the member(s) of the Company (unless otherwise provided in this Indenture).

FERC Order” has the meaning given in Schedule A of the CSAA.

Finance Documents” has the meaning given in Schedule A of the CSAA; provided that such term shall include any other document designated as a Finance Document by the Company and the Collateral Agent (on instruction from Requisite Secured Parties).

Fitch” has the meaning given in Schedule A of the CSAA.

FTA Authorization” has the meaning given in Schedule A of the CSAA.

GAAP” has the meaning given in Schedule A of the CSAA.

Galp” means Galp Energia E&P B.V.

Gas” has the meaning given in Schedule A of the CSAA.

Gas Hedge Provider” has the meaning given in Schedule A of the CSAA.

Gas Supply Agreement” has the meaning given in Schedule A of the CSAA.

Gas Transportation Agreements” means:

 

  (a)

Precedent Agreement for Firm Natural Gas Transportation Service, dated as of August 22, 2016, by and between ANR Pipeline Company and Venture Global Calcasieu Pass, LLC, as superseded by the Amended and Restated Precedent Agreement for Firm Natural Gas Transportation Service, dated as of December 21, 2018 (as supplemented by FTS-1 Service Agreement (Contract No. 133755), dated January 22, 2020, with respect to the Phase I Project and FTS-1 Service Agreement (Contract No. 133756), dated January 22, 2020, with respect to the Phase II Project);

 

13


  (b)

Precedent Agreement for Firm Natural Gas Transportation Service, dated as of May 13, 2019, between EnLink Midstream Operating LP, Venture Global Calcasieu Pass, LLC, Bridgeline Holdings, L.P., and Sabine Pipe Line LLC (as supplemented by the Service Agreement for Firm Transportation Service, dated as of August 19, 2019, between Venture Global Calcasieu Pass, LLC and Sabine Pipe Line LLC);

 

  (c)

Service Agreement, dated as of September 8, 2020, by and between Texas Eastern Transmission, LP and Venture Global Calcasieu Pass, LLC, together with the Negotiated Rate Letter, dated as of September 8, 2020, between Venture Global Calcasieu Pass, LLC and Texas Eastern Transmission, LP; and

 

  (d)

after a Permitted Pipeline Sale, each PPS Gas Agreement.

Global Note Legend” means (i) in the case of the Initial Notes, the legend set forth in Section 2.06(g)(2) and (ii) in the case of any Additional Notes, a legend required or permitted by Section 2.01(d).

Global Notes” means, individually and collectively, each of the Restricted Global Notes, the Unrestricted Global Notes and any Additional Notes issued as a Global Note, deposited with or on behalf of and registered in the name of the Depositary or its nominee, issued in accordance with Section 2.01 and Section 2.06.

Governmental Authorities” has the meaning given in Schedule A of the CSAA.

Government Securities” means securities that are:

 

  (a)

direct obligations of the United States of America for the timely payment of which its full faith and credit is pledged; or

 

  (b)

obligations of a Person controlled or supervised by and acting as an agency or instrumentality of the United States of America the timely payment of which is unconditionally guaranteed as a full faith and credit obligation by the United States of America,

which, in either case, are not callable or redeemable at the option of the issuers thereof, and shall also include a depository receipt issued by a bank (as defined in Section 3(a)(2) of the Securities Act), as custodian with respect to any such Government Securities or a specific payment of principal of or interest on any such Government Securities held by such custodian for the account of the holder of such depository receipt; provided that (except as required by law) such custodian is not authorized to make any deduction from the amount payable to the holder of such depository receipt from any amount received by the custodian in respect of the Government Securities or the specific payment of principal of or interest on the Government Securities evidenced by such depository receipt.

Guarantor” means TransCameron Pipeline, LLC, a limited liability company organized under the laws of the State of Delaware, which is a direct wholly owned Subsidiary of the Pledgor, and any Subsidiary of the Company or TCP that accedes to the CSAA from time to time as permitted under the Finance Documents then in effect as a Guarantor for the benefit of all Senior Creditors, pursuant to Section 11.15 (Additional Guarantors) of the CSAA.

 

14


Hedging Bank” has the meaning given in Schedule A of the CSAA.

Hedging Instruments” has the meaning given in Schedule A of the CSAA.

Hedging Termination Amount” has the meaning given in Schedule A of the CSAA.

Historical DSCR” means for any Calculation Period, the ratio of:

 

  (a)

the Cash Flow Available for Debt Service for such period; to

 

  (b)

Debt Service for such period (other than (i) pursuant to voluntary prepayments or mandatory prepayments, (ii) LC Costs, (iii) interest in respect of the Senior Debt paid prior to the end of the Term Loan Availability Period (or, if no Loans or Senior Debt Commitments remain outstanding, any debt service that was pre-funded by the incurrence of Permitted Senior Debt, one of the use of proceeds of which was expressly for this purpose), (iv) under any Permitted Hedging Instruments in respect of interest rates, in each case paid prior to the end of the Term Loan Availability Period, (v) net payable amounts under Permitted Hedging Instruments that are not in respect of interest rates, (vi) Hedging Termination Amounts, and (vii) Working Capital Debt and any Debt Service payable thereunder).

Holder” means a Person in whose name a Note is registered.

IAI Global Note” means a Global Note issued in accordance with 2.01(c)(1)(B) hereof.

Impairment” has the meaning given in Schedule A of the CSAA. “Impair” and “Impaired” shall have a corresponding meaning.

Indebtedness” has the meaning given in Schedule A of the CSAA.

Indenture Payment Date” means this Indenture payment dates of February 15 and August 15.

Independent Accountants” means any independent firm of accountants of recognized standing in the relevant jurisdiction.

Independent Engineer” means Lummus Consultants International LLC and any replacement thereof appointed (a) pursuant to the terms of the Common Terms Agreement if Loans or Senior Debt Commitments in connection therewith are outstanding or (b) if no Loans or Senior Debt Commitments in connection therewith are outstanding, by the Requisite Secured Parties, and if no Event of Default shall then be Continuing, after consultation with the Company.

Indirect Participant” means a Person who holds a beneficial interest in a Global Note through a Participant.

 

15


Initial LNG Buyers” means (a) Shell, Edison, Galp, BP, Repsol and PGNiG and (b) for purposes of this Indenture, Venture Global Commodities, LLC.

Initial LNG SPA Guarantees” means:

 

  (a)

the Guarantee, dated as of February 4, 2016, by Shell Oil Company in favor of the Company, as amended by First Amendment to Guarantee, dated as of March 5, 2018;

 

  (b)

the Guarantee, dated as of May 17, 2018, by BP International Limited in favor of the Company;

 

  (c)

the Guarantee, dated as of May 18, 2018, by Galp Energia, SGPS, S.A. in favor of the Company;

 

  (d)

the Guarantee, dated as of August 14, 2018, by Repsol Exploracion, S.A. in favor of the Company; and

 

  (e)

any other guarantee delivered to the Company under an Initial LNG SPA.

Initial LNG SPAs” means the following LNG SPAs entered into between the Company and the Initial LNG Buyers on or before the Credit Facilities Closing Date:

 

  (a)

the Amended and Restated LNG Sales and Purchase Agreement (FOB) between the Company and Shell, dated as of April 4, 2018, as amended by First Amendment to Amended and Restated LNG Sales and Purchase Agreement (FOB), dated as of August 10, 2018, and Second Amendment to Amended and Restated LNG Sales and Purchase Agreement (FOB), dated as of June 14, 2019, and as supplemented by Notice of CP Satisfaction Date, dated as of August 19, 2019;

 

  (b)

the LNG Sales and Purchase Agreement (FOB) between the Company and Edison, dated as of September 25, 2017, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of February 28, 2018, Amendment No. 2 to LNG Sales and Purchase Agreement (FOB), dated as of June 13, 2018, Amendment No. 3 to LNG Sales and Purchase Agreement (FOB), dated as of December 13, 2018, and Amendment No. 4 to LNG Sales and Purchase Agreement (FOB), dated as of June 10, 2019, and supplemented by Waiver of Condition Precedent, dated as of September 4, 2018, by Edison;

 

  (c)

the LNG Sales and Purchase Agreement (FOB) between the Company and Galp, dated as of April 30, 2018, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of December 20, 2018 and as supplemented by Notice of CP Satisfaction Date, dated as of August 19, 2019;

 

  (d)

the LNG Sales and Purchase Agreement (FOB) between the Company and BP, dated as of May 17, 2018 and as supplemented by Notice of CP Satisfaction Date, dated as of August 19, 2019;

 

16


  (e)

the LNG Sales and Purchase Agreement (FOB) between the Company and Repsol, dated as of August 14, 2018, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of June 10, 2019 and Amendment No. 2 to LNG Sales and Purchase Agreement (FOB) dated as of June 10, 2020, and as supplemented by Notice of CP Satisfaction Date dated as of August 19, 2019;

 

  (f)

the LNG Sales and Purchase Agreement (FOB) between the Company and PGNiG, dated as of September 28, 2018, as supplemented by letter agreement dated June 24, 2019, and as supplemented by Notice of CP Satisfaction Date dated as of August 19, 2019 (collectively, the LNG Sales and Purchase Agreements described in clauses (a) – (f) of this definition, the “Foundation LNG SPAs”); and

 

  (g)

the Excess Capacity LNG SPA.

Initial Notes” means, collectively, the 2029 Notes and the 2031 Notes.

Initial Permitted Senior Debt Hedging Instruments” has the meaning given in Schedule A of the CSAA.

Initial Purchasers” means, with respect to the Initial Notes, Morgan Stanley & Co. LLC, J.P. Morgan Securities LLC, BofA Securities, Inc., Goldman Sachs & Co. LLC, ING Financial Markets LLC, Mizuho Securities USA LLC, Natixis Securities Americas LLC, Nomura Securities International, Inc., RBC Capital Markets, LLC, Santander Investment Securities Inc., Scotia Capital (USA) Inc., SMBC Nikko Securities America, Inc., ICBC Standard Bank Plc and with respect to any Additional Notes, the purchaser or purchasers of such Additional Notes from the Company.

Initial Senior Debt” has the meaning given in Schedule A of the CSAA.

Institutional Accredited Investor” means an institution that is an “accredited investor” as defined in Rule 501(a)(1), (2), (3) or (7) under the Securities Act, who is not also a QIB.

Insurance/Condemnation Proceeds Account” has the meaning given in Schedule A of the CSAA.

Insurance Proceeds” has the meaning given in Schedule A of the CSAA.

Intercreditor Agent” has the meaning given in Schedule A of the CSAA.

Intercreditor Agreement” has the meaning given in Schedule A of the CSAA.

Interest Payment Date” means February 15 and August 15 of each year, commencing on February 15, 2022, or if any such day is not a Business Day, the next succeeding Business Day.

 

17


Investment” means, for any Person:

 

  (a)

the acquisition (whether for cash, property of such Person, services or securities or otherwise) of capital stock, bonds, notes, debentures, partnership or other ownership interests or other securities of any other Person or any agreement to make any such acquisition (including any “short sale” or any other sale of any securities at a time when such securities are not owned by the Person entering into such sale);

 

  (b)

the making of any deposit with, or advance, loan or other extension of credit to, any other Person (including the purchase of property from another Person subject to an understanding or agreement, contingent or otherwise, to resell such property to such Person, but excluding any such advance, loan or extension of credit having a term not exceeding 90 days representing the purchase price of inventory or supplies sold in the ordinary course of business); and

 

  (c)

the entering into of any guarantee of, or other contingent obligation (other than an indemnity which is not a guarantee) with respect to, Indebtedness or other liability of any other Person;

provided, that Investment shall not include amounts deposited pursuant to the escrow agreement entered with respect to disputed amounts under any engineering, procurement and construction contract then in effect.

Investment Grade” means one long-term unsecured credit rating equal to or better than (a) Baa3 by Moody’s, (b) BBB- by S&P, (c) BBB- by Fitch or (d) any comparable credit ratings by any other nationally recognized statistical rating organizations.

Investment Grade LNG Buyer” means an LNG Buyer that:

 

  (a)

has, or has its obligations guaranteed by an entity that has, at least two Investment Grade ratings;

 

  (b)

has, or has its obligations guaranteed by an entity that has, one Investment Grade rating and a tangible net worth of at least $3.0 billion per MTPA of LNG committed to be purchased by such LNG Buyer pursuant to its LNG SPA; or

 

  (c)

for the purposes of LNG SPAs under Section 4.06, Section 4.21, or Section 4.29, has its obligations under the applicable LNG SPA in an amount equal to the greater of (i) 50% of the total undiscounted present value of the projected payments thereunder during the remaining term of such LNG SPA and (ii) 100% of the total undiscounted present value of its projected payments thereunder during the lesser of (A) the succeeding five (5) years under such LNG SPA and (B) the remaining term of such LNG SPA, supported by a letter of credit issued by an Acceptable Bank.

LC Costs” has the meaning given in Schedule A of the CSAA.

Leases” means:

 

  (a)

the Amended and Restated Ground Lease Agreement, dated as of June 20, 2019, by and between the Company and Henry Venture, LLC, amending and restating the Ground Lease Agreement dated as of March 11, 2019, as amended by that certain First Amendment to Ground Lease Agreement dated as of March 25, 2019; and

 

18


  (b)

the Amended and Restated Ground Lease Agreement, dated as of July 15, 2019, by and between the Company and JADP Venture, LLC, amending and restating the Ground Lease Agreement dated as of March 14, 2019, as amended by that certain First Amendment to Ground Lease Agreement dated as of March 25, 2019.

Lien” has the meaning given in Schedule A of the CSAA.

LNG” has the meaning given in Schedule A of the CSAA.

LNG Buyer” has the meaning given in Schedule A of the CSAA.

LNG Facility” or “Facility” means the approximately 10 MTPA nameplate LNG liquefaction and export project located alongside the Calcasieu Ship Channel in Cameron Parish, Louisiana, consisting of nine integrated single mixed refrigerant liquefaction blocks and supporting facilities, three natural gas pre-treatment units to remove water and acid gases from feed gas prior to liquefaction (each capable of supporting 50% of the nameplate capacity), two 200,000 cubic meter cryogenic LNG storage tanks, a marine terminal with two LNG berthing docks that can accommodate vessels up to at least 185,000 cubic meters in capacity, a 620 megawatt air-cooled combined-cycle gas-fired power plant with an additional 25 megawatt gas- fired turbine with selective catalyst reduction, in each case (i) with related onsite utilities and supporting infrastructure and (ii) as such facilities may be improved, replaced, modified, changed or expanded in accordance with the Finance Documents.

LNG Production System” means LPS1, LPS2 or LPS3, as applicable.

LNG Production System RFSU” means, with respect to an LNG Production System, all of the following conditions are satisfied: (a) Kiewit has completed all applicable Work in accordance with the EPC Contract, including Exhibit S to the EPC Contract, to ensure that such LNG Production System is ready to receive and utilize feed gas, (b) Kiewit has achieved mechanical completion with respect to such LNG Production System, and (c) Kiewit has delivered to the Company an LNG Production System RFSU certificate in accordance with the EPC Contract.

LNG Production System Substantial Completion” has the meaning assigned to such term in the EPC Contract.

LNG SPA” has the meaning given in Schedule A of the CSAA.

LNG SPA Mandatory Prepayment” has the meaning given in Schedule A of the CSAA.

Loan Facility Declared Default” has the meaning given in Schedule A of the CSAA.

Loan Facility Event of Default” has the meaning given in Schedule A of the CSAA.

 

19


Loan Participant” means each Person (other than a natural Person, or a holding company, investment vehicle or trust for, or owned and operated for the primary benefit of, a natural Person) to whom a Facility Lender may sell participations from time to time.

Loans” has the meaning given in Schedule A of the CSAA.

Long Derivative Instruments” means, as to any person, a Derivative Instrument (i) the value of which to such person generally increases, and/or the payment or delivery obligations of such person under which generally decrease, with positive changes in the financial performance and/or position of the Company and/or (ii) the value of which to such person generally decreases, and/or the payment or delivery obligations of such person under which generally increase, with negative changes in the financial performance and/or position of the Company.

LPS1” means the systems and sub-systems comprising a portion of the Facility and including the first four (4) blocks.

LPS2” means the systems and sub-systems comprising a portion of the Facility and including two (2) blocks.

LPS3” means the systems and sub-systems comprising a portion of the Facility and including the final three (3) blocks.

LTS Purchase Order” means that certain the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of September 25, 2018, by and between the Company and BHGE, as amended by Change Order No. 1 dated as of June 24, 2019, Letter Agreement dated June 24, 2019, Letter Agreement dated August 12, 2019, Change Order No. 2 dated as of December 11, 2019, Change Order No. 3 dated as of March 31, 2020, Change No. 4 dated as of September 24, 2020, Change Order No. 5 dated January 14, 2021, Change Order No. 6 dated November 24, 2020, Change Order No. 7 dated as of December 16, 2020, and Change Order No. 8 dated April 12, 2021.

Manager” has the meaning given in Schedule A of the CSAA.

Marine Works Construction Agreement” means that certain Construction Agreement relating to Marine Works, dated as of January 24, 2017, by and between the Company and Weeks Marine, as amended by Amendment No. 1 to Construction Agreement, dated as of December 13, 2017, Amendment No. 2 to Construction Agreement, dated as October 5, 2018, Amendment No. 3 to Construction Agreement, dated as of March 5, 2019, Amendment No. 4 to Construction Agreement, dated as of June 28, 2019, and Amendment No. 5, dated as of July 3, 2019, as supplemented by the letter agreement dated July 3, 2019, and as amended by Change Order No. 1, dated October 17, 2019, between the Company and Weeks Marine (Marine Works), Change Order No. 2, dated as of July 1, 2020, Change Order No. 3, dated as of October 20, 2020, Change Order No. 4, dated January 27, 2021, Change Order No. 5, dated April 2, 2021, Change Order No. 6, dated as of April 27, 2021, and Change Order No. 7, dated as of July 9, 2021.

Material Adverse Effect” has the meaning given in Schedule A of the CSAA.

 

20


Material Construction Contracts” means, together, each of the following documents:

 

  (a)

the EPC Contract;

 

  (b)

the Pipeline Construction Agreement;

 

  (c)

the LTS Purchase Order;

 

  (d)

the PIS Purchase Order;

 

  (e)

the Pretreatment Contract;

 

  (f)

the Marine Works Construction Agreement;

 

  (g)

the Storm Surge Wall Construction Agreement; and

 

  (h)

the Storage Tanks EPC Contract.

Material Project Agreements” means:

 

  (a)

the Initial LNG SPAs;

 

  (b)

the Initial LNG SPA Guarantees;

 

  (c)

the Material Construction Contracts;

 

  (d)

the Gas Transportation Agreements;

 

  (e)

from and after LNG Production System RFSU (as defined in the EPC Contract) with respect to LPS1, the Gas Supply Agreement;

 

  (f)

the Service Agreements (other than the agreement described in clause (e) of the definition thereof);

 

  (g)

from and after the entry into such agreement, the agreement described in clause (e) of the definition of “Service Agreements;”

 

  (h)

the Leases;

 

  (i)

the Parent Guarantees;

 

  (j)

the Access License Agreements;

 

  (k)

the Pipeline Service Agreements;

 

  (l)

any additional contract with obligations and liabilities thereunder (A) equal to or in excess of $20 million per year and a committed term of at least five (5) years, with respect to any contract for the purchase of natural gas by, or supply of natural gas to, the Company, (B) equal to or in excess of $50 million per year and a committed term of at least five (5) years, with respect to any contract for the delivery and sale of LNG by the Company, and (C) equal to or in excess of $50 million per year and a committed term of at least two (2) years, with respect to any other contract;

 

21


  (m)

any parent guarantee related to any agreement described in (e) or (l) above or, to the extent not described in (b) above, related to any Initial LNG SPA or Qualifying LNG SPA; and

 

  (n)

any replacement of any existing agreement described in (a) through (m) above.

Material Project Counterparties” means each of the Construction Contractors, the Initial LNG Buyers, Shell Oil Company, Galp Energia, SGPS, S.A., BP International Limited, Repsol Exploracion, S.A., Texas Eastern Transmission, LP, ANR Pipeline Company, Bridgeline Holdings, L.P., EnLink Midstream Operating, LP, Sabine Pipe Line LLC, Indigo Minerals LLC, Calcasieu Pass Operations, LLC, Venture Global Services, LLC, TransCameron Operations, LLC, Henry Venture, LLC, JADP Venture, LLC, General Electric Company, McDermott International, Inc., Honeywell International Inc., CP Marine Offloading, LLC and each other party (other than an Obligor) to a Material Project Agreement.

Moody’s” has the meaning given in Schedule A of the CSAA.

Mortgage” has the meaning given in Schedule A of the CSAA.

MTPA” means million tonnes per annum.

Net Cash Proceeds” has the meaning given in Schedule A of the CSAA.

Net Short” means, with respect to a noteholder or beneficial owner, as of a date of determination, either (i) the value of its Short Derivative Instruments exceeds the sum of (x) the value of its notes plus (y) the value of its Long Derivative Instruments as of such date of determination or (ii) it is reasonably expected that such would have been the case were a Failure to Pay or Bankruptcy Credit Event (each as defined in the 2014 ISDA Credit Derivatives Definitions) to have occurred with respect to the Company immediately prior to such date of determination.

Non-FTA Authorization” has the meaning given in Schedule A of the CSAA.

Non-U.S. Person” means a Person who is not a U.S. Person.

Notes” means the Initial Notes and any Additional Notes, unless the context otherwise requires.

Notes Issue Date” means the first date of the original issuance of the Notes under this Indenture.

Note Guarantee” means the guarantee by each Guarantor of the Company’s obligations under this Indenture and the Notes, as set forth in the provisions of this Indenture.

O&M Agreement” has the meaning given in Schedule A of the CSAA.

 

22


Obligors” means the Company, TCP and any other Guarantor; provided that, from and after a Permitted Pipeline Sale, TCP shall not be an Obligor under this Indenture.

Offering Memorandum” means that certain confidential offering memorandum, dated as of July 29, 2021, pursuant to which the Initial Notes were first offered to eligible purchasers in a private placement.

Officer’s Certificate” means a certificate signed by one Authorized Officer of the Company, which officer must be the principal executive officer, the principal financial officer, the treasurer or the principal accounting officer, that meets the requirements of Section 13.05 hereof.

Operation and Maintenance Expenses” has the meaning given in Schedule A of the CSAA.

Operational” has the meaning give in Schedule A of the CSAA.

Operator” has the meaning give in Schedule A of the CSAA.

Opinion of Counsel” means an opinion or opinions from legal counsel who is reasonably acceptable to the Trustee, that meets the requirements of Section 13.05. The counsel may be an employee of, or counsel to, the Company, any Subsidiary of the Company or the Trustee.

Parent Guarantees” means:

 

  (a)

Seller Parent Guaranty Agreement, dated as of September 28, 2018, by General Electric Company for the benefit of Company, relating to the LTS Purchase Order;

 

  (b)

Seller Parent Guaranty Agreement, dated as of September 28, 2018, by General Electric Company for the benefit of the Company, relating to the PIS Purchase Order;

 

  (c)

Parent Guarantee, dated as of August 5, 2019, by McDermott International, Inc., in favor of the Company;

 

  (d)

Parent Guarantee, dated as of December 21, 2018, by Honeywell International Inc. in favor of the Company; and

 

  (e)

the EPC Contract Guaranty.

Participant” means, with respect to the Depositary, Euroclear or Clearstream, a Person who has an account with the Depositary, Euroclear or Clearstream, respectively (and, with respect to DTC, shall include Euroclear and Clearstream).

Performance Liquidated Damages” has the meaning given in Schedule A of the CSAA.

Permit” has the meaning given in Schedule A of the CSAA.

 

23


Permitted Business” means (a) the development, construction, operation, expansion, reconstruction, debottlenecking, improvement, maintenance and ownership of the Development (including, without limitation, any carbon capture and sequestration facilities relating to the Development) or related to or using by-products of the Development, all activity reasonably necessary or undertaken in connection with the foregoing and any activities incidental or related to any of the foregoing, including, the development, construction, operation, maintenance, financing and ownership of any facilities reasonably related to the Development or related to or using by-products of the Development and (b) the buying, selling, storing and transportation of hydrocarbons for use in connection with the Development or related to or using by-products of the Development.

Permitted Completion Amount” has the meaning given in Schedule A of the CSAA.

Permitted Development Expenditures” means Development Expenditures that:

 

  (a)

are required by applicable law or regulations, any consent from a Governmental Authority, Industry Standards or Prudent Industry Practice applicable to the Development; or

 

  (b)

are otherwise used for the Development; or

 

  (c)

are incurred in connection and in compliance with Section 4.27 or Section 4.28; and are funded from (i) Equity Funding not otherwise committed to other expenditure for the Development, (ii) Insurance Proceeds and Condemnation Proceeds to the extent permitted by Article 5 of the CSAA or proceeds of dispositions to the extent permitted by Section 12.17 of the Common Terms Agreement while in effect or any equivalent provision of any other Senior Debt Instrument or if no Senior Debt Instrument is then in effect, the provisions of such Senior Debt Instrument immediately prior to its termination, (iii) Retained Excess Cash Flow, (iv)Cash Flow permitted to be used for Operation and Maintenance Expenses (pursuant to clauses (c) and (k) of the definition thereof) or (v) PDE Senior Debt permitted to be incurred pursuant to Section 4.09(d), Expansion Senior Debt permitted to be incurred pursuant to Section 4.09(c) or other Indebtedness permitted to be incurred under Section 4.08, in the case of each of the foregoing sub-clauses (i), (ii) and (iv), which use for the contemplated development could not reasonably be expected to have a Material Adverse Effect.

Permitted Finance Costs” means, for any period, the sum of all amounts of principal, interest, fees and other amounts payable in relation to Indebtedness (other than Senior Debt and other than LC Costs and other amounts payable in relation to Indebtedness that constitute Operation and Maintenance Expenses) permitted by Section 12.14(b) (including guarantees thereof permitted under Section 12.15 of the Common Terms Agreement during such period) plus all amounts payable during such period pursuant to Permitted Hedging Instruments that are not secured, plus any amounts required to be deposited in margin accounts pursuant to Permitted Hedging Instruments; provided that Permitted Finance Costs will not include funds categorized as Operation and Maintenance Expenses under the last sentence of the definition thereof. For purposes of this Indenture, “Permitted Finance Costs” shall include amounts payable in relation to Indebtedness (other than Senior Debt and other than LC Costs and other amounts payable in relation to Indebtedness that constitute Operation and Maintenance Expenses) permitted by this Indenture, and shall not include funds categorized as Operation and Maintenance Expenses under the exception thereunder for obligations to repay advances in relation to secured Permitted Hedging Instruments or Indebtedness permitted by this Indenture.

 

24


Permitted Hedging Instrument” means (a) each Initial Permitted Senior Debt Hedging Instrument; or (b) a Hedging Instrument entered into by the Company in the ordinary course of business and that (i) is with a Hedging Bank, a Gas Hedge Provider or any other party that is a counterparty to a Hedging Instrument, and (ii) is entered for non-speculative purposes and is on arm’s-length terms.

Permitted Investment” means:

 

  (a)

Authorized Investments;

 

  (b)

by way of trade credit in the ordinary course of business;

 

  (c)

as specifically contemplated under the Finance Documents to which the Trustee is a party or by the terms of a Material Project Agreement as long as (i) such Material Project Agreement was in place on the Notes Issue Date, but only to the extent permitted by such Material Project Agreement on the Notes Issue Date, (ii) such Material Project Agreement was approved by the Intercreditor Agent at a time when at least $1 billion of Loans or Senior Debt Commitments in connection therewith were outstanding or (iii) such Investment does not exceed $15,000,000 in the aggregate with all other Investments permitted under this clause (c)(iii);

 

  (d)

advance payments to contractors in the ordinary course of business on usual commercial terms;

 

  (e)

Investments among and between the Company, TCP and/or their Restricted Subsidiaries;

 

  (f)

any Investment by the Company, TCP and/or their Restricted Subsidiaries in a Person, if as a result of such investment such Person is merged or consolidated with or into, or transfers or conveys substantially all of its assets to, or is liquidated into, the Company, TCP and/or their Restricted Subsidiaries;

 

  (g)

Investments existing on the Notes Issue Date;

 

  (h)

repurchases of the Senior Notes;

 

  (i)

Investments received as a result of a foreclosure by the Company, TCP and/or their Restricted Subsidiaries with respect to any secured investment in default;

 

  (j)

surety and performance bonds and workers’ compensation, utility, lease, tax, performance and similar deposits and prepaid expenses in the ordinary course of business, including cash deposits incurred in connection with Gas purchases;

 

25


  (k)

any Investment in any Person solely in exchange for the issuance of Equity Interests (other than Equity Interests that constitute Indebtedness) of the Company or TCP;

 

  (l)

amounts deposited pursuant to the escrow agreement entered into with respect to disputed amounts under any engineering, procurement and construction contract or another construction contract with respect to development of the Project Facilities as permitted under the Finance Documents;

 

  (m)

advances, deposits and prepayments for purchases of any assets, including any Equity Interests;

 

  (n)

guarantees of Indebtedness pursuant to Section 4.08;

 

  (o)

Investments pursuant to Permitted Hedging Instruments;

 

  (p)

any Investment made as a result of the receipt of non-cash consideration from an Asset Sale that was made pursuant to and in compliance with Section 4.12;

 

  (q)

any Investments received in compromise or resolution of (i) obligations of trade creditors or customers that were incurred in the ordinary course of business of the Company, TCP and/or their Restricted Subsidiaries, including pursuant to any plan of reorganization or similar arrangement upon the bankruptcy or insolvency of any trade creditor or customer; or (ii) litigation, arbitration or other disputes with Persons who are not Affiliates;

 

  (r)

(i) advances to or reimbursements of employees for moving, entertainment and travel expenses, drawing accounts and similar expenditures in the ordinary course of business; and (ii) loans or advances to employees made in the ordinary course of business of the Company, TCP and/or their Restricted Subsidiaries in an aggregate principal amount not to exceed $2,500,000 at any one time outstanding;

 

  (s)

advances to customers or suppliers in the ordinary course of business that are, in conformity with GAAP, recorded as accounts receivable, prepaid expenses or deposits on the balance sheet of the Company, TCP and/or their Restricted Subsidiaries and endorsements for collection or deposit arising in the ordinary course of business; and

 

  (t)

other Investments in any Person having an aggregate Fair Market Value (measured on the date each such Investment was made and without giving effect to subsequent changes in value), when taken together with all other investments made pursuant to this clause (t) that are at the time outstanding not to exceed $50,000,000.

Permitted Liens” means:

 

  (a)

Liens for taxes not delinquent or being contested in good faith and by appropriate proceedings in relation to which appropriate reserves are maintained and liens for customs duties that have been deferred in accordance with the laws of any applicable jurisdiction;

 

26


  (b)

deposits or pledges to secure obligations under workmen’s compensation, old age pensions, social security or similar laws or under unemployment insurance;

 

  (c)

deposits or other financial assurances to secure bids, tenders, contracts (other than for borrowed money), leases, concessions, licenses, statutory obligations, surety and appeal bonds (including any bonds permitted under the Material Construction Contracts and any other engineering, procurement or construction contracts), performance bonds and other obligations of like nature arising in the ordinary course of business and cash deposits incurred in connection with Gas purchases;

 

  (d)

mechanics’, workmen’s, materialmen’s, suppliers’, warehouse, Liens of lessors and sublessors or other like Liens arising or created in the ordinary course of business with respect to obligations that are not due or that are being contested in good faith;

 

  (e)

servitudes, easements, rights of way, encroachments and other similar encumbrances burdening the Project Facilities’ land that are granted in the ordinary course, imperfections of title on real property, and restrictive covenants, zoning restrictions, licenses or conditions on the grant of real property (in relation to such real property); provided that such servitudes, easements, rights of way, encroachments and other similar encumbrances, imperfections, restrictive covenants, restrictions, licenses or conditions do not materially interfere with the Development as contemplated in the Finance Documents and the Material Project Agreements;

 

  (f)

Liens to secure Indebtedness permitted by clauses (h) and (p) of Section 4.08;

 

  (g)

the Security Interests;

 

  (h)

Liens in the ordinary course of business arising from or created by operation of applicable law or required in order to comply with any applicable law;

 

  (i)

Liens in the ordinary course of business over any assets (the aggregate value of which assets at the time any such Lien is granted does not exceed $100,000,000);

 

  (j)

contractual or statutory rights of set-off (including netting) granted to the Obligors’ bankers, (i) under any Permitted Hedging Instrument or any Material Project Agreement as long as (A) such Material Project Agreement was in place on the Notes Issue Date but only to the extent permitted by such Material Project Agreement on the Notes Issue Date, (B) such Material Project Agreement was approved by the Intercreditor Agent at a time when at least $1 billion of Loans or Senior Debt Commitments in connection therewith were outstanding or (C) the amount of collateral affected by such Lien does not exceed $15,000,000 in the aggregate with all other Liens permitted under this clause (C); and (ii) that could not reasonably be expected to cause a Material Adverse Effect;

 

  (k)

deposits or other financial assurances to secure reimbursement or indemnification obligations in respect of letters of credit or in respect of letters of credit put in place by an Obligor and payable to suppliers, service providers, insurers or landlords in the ordinary course of business;

 

27


  (l)

Liens that are scheduled exceptions to the coverage afforded by a Title Policy on the Notes Issue Date or later date of amendment of a Title Policy or delivery of a new Title Policy;

 

  (m)

legal or equitable encumbrances (other than any attachment prior to judgment, judgment lien or attachment in aid of execution on a judgment) deemed to exist by reason of the existence of any pending litigation or other legal proceeding if the same is effectively stayed or the claims secured thereby are being contested in good faith and by appropriate proceedings and an appropriate reserve has been established in respect thereof in accordance with GAAP;

 

  (n)

the Liens created pursuant to the Real Property Documents;

 

  (o)

Liens created by any fee owner under a Lease, to the extent permitted by such Lease;

 

  (p)

Liens by any Obligor in favor of any other Obligor;

 

  (q)

Liens arising out of judgments or awards not constituting an Event of Default so long as an appeal or proceeding for review is being prosecuted in good faith and for the payment of which adequate cash reserves, bonds or other cash equivalent security have been provided or are fully covered by insurance (other than any customary deductible); and

 

  (r)

Liens arising from Sharing Arrangements permitted as described in Section 4.28.

Permitted Payment” means, without duplication as to amounts allowed to be distributed under any other provision of the Common Terms Agreement:

 

  (a)

payments to an Affiliate of the Company to permit such Affiliate to pay its reasonable accounting, legal and administrative expenses when due, in an aggregate amount not to exceed $5,000,000 per calendar year (escalating annually in accordance with the applicable Material Project Agreements); and

 

  (b)

(i) with respect to any periods (or portions thereof) ending before the Project Completion Date, the amount necessary for payment to an Affiliate of the Company to enable it (or, if such Affiliate is a flow-through entity for U.S. federal income tax purposes, its beneficial owners) to pay its (or such beneficial owners’) income tax liability with respect to income generated by the Obligors as a result of sales pursuant to the LNG SPAs for any periods (or portions thereof) ending prior to the Project Completion Date and (ii) with respect to any periods (or portions thereof) ending after the Project Completion Date, the amount necessary for payment to an Affiliate of the Company to enable it (or, if such Affiliate is a flow-through entity for U.S. federal income tax purposes, its beneficial owners) to pay its (or such beneficial owners’) income tax liability with respect to income generated by the Obligors, provided that such income tax liability shall be determined hypothetically based on the aggregate net taxable income of the Obligors and the highest combined tax rate applicable to an individual residing in New York, New York for the applicable period.

 

28


Permitted Pipeline Sale” means any sale of the Capital Stock of TCP or the TransCameron Pipeline to a Qualified Pipeline Owner which satisfies the following conditions: (a) after giving effect to any such sale, and taking into account any payments to be made by the Company to TCP or the owner of the TransCameron Pipeline through the terms of the Qualifying LNG SPAs, the amount of all Senior Debt (excluding Working Capital Debt and excluding all Indebtedness under Permitted Senior Debt Hedging Instruments) outstanding after giving effect to such sale, is capable of being amortized to a zero balance by the termination date of the last to terminate of the Qualifying LNG SPAs then in effect and produces a Projected Fixed DSCR that is not less than 1.40:1.00 through the terms of such Qualifying LNG SPAs, with such calculations using such Qualifying LNG SPAs in respect of which there is in effect their Required Export Authorizations which are not Impaired, and using an interest rate equal to the weighted average interest rate of all Senior Debt (other than Working Capital Debt) then outstanding; (b) no Event of Default or Unmatured Event of Default has occurred and is Continuing or would reasonably be expected to occur as a result of such sale; (c) the Company has (i) retained existing gas transportation agreements in place between the Company and TCP prior to giving effect to such sale, or (ii) entered into one or more binding agreements with TCP (or the owner of the TransCameron Pipeline) relating to the Company’s use of the TransCameron Pipeline so that the Company is able to perform its obligations in accordance with the Qualifying LNG SPAs through the last to terminate of such Qualifying LNG SPAs, in each case, through the terms of such Qualifying LNG SPAs (each such agreement contemplated by this clause (c), a “PPS Gas Agreement”); (d) a Direct Agreement is in place with respect to each PPS Gas Agreement; (e) each PPS Gas Agreement entered into pursuant to clause (c)(ii) above (if any) is undertaken on fair and commercially reasonable terms that are not less favorable in the aggregate to the Company than would be obtained in a comparable agreement with independent parties acting at arm’s length (or, if there is no comparable arm’s-length transaction, then on terms reasonably determined by the Board of Directors (or equivalent governing body) of the Company to be fair and reasonable); (f) such sale is consummated in compliance with the FERC Order and, after giving effect to such sale, the FERC Order remains in full force and effect; (g) the Company shall have delivered to the Trustee a certificate of an Authorized Officer of the Company certifying that no Material Adverse Effect will occur, or would reasonably be expected to occur, as a result of such sale; (h) the Company shall have received letters from any two Recognized Credit Rating Agencies (or if only one Recognized Credit Rating Agency is then rating the Notes of such series, the Company shall have received a letter from that Recognized Credit Rating Agency) to the effect that the Recognized Credit Rating Agency has considered the contemplated sale and that, if such sale occurs, there would be no downgrading in the rating such Recognized Credit Rating Agency would provide for the Notes of such series as of the date of such sale; and (i) the Trustee has received a certificate of an Authorized Officer of the Company confirming that each of the conditions set forth in clauses (a) through (h) above has been satisfied and setting forth the calculation of Projected Fixed DSCR in clause (a) above.

 

29


Permitted Refinancing Indebtedness” means any Indebtedness of the Company, TCP or any of their Restricted Subsidiaries incurred under clauses (i) or (j) of the definition of “Permitted Indebtedness,” issued in exchange for, or the net proceeds of which are used to renew, refund, refinance, replace, defease or discharge other Indebtedness of the Company, TCP or any of their Restricted Subsidiaries (other than intercompany Indebtedness); provided that the principal amount (or accreted value, if applicable) of such Permitted Refinancing Indebtedness does not exceed the principal amount (or accreted value, if applicable) of the Indebtedness renewed, refunded, refinanced, replaced, defeased or discharged (plus all accrued interest on the Indebtedness, any amounts deposited in a debt service reserve or similar reserve account in connection with the issuance of such Permitted Refinancing Indebtedness and the amount of all fees and expenses, including premiums and discounts incurred in connection therewith).

Permitted Senior Debt Hedging Instrument” means a Permitted Hedging Instrument in respect of which the Hedging Banks have acceded to the CSAA.

Person” has the meaning given in Schedule A of the CSAA.

PGNiG” means Polskie Goìrnictwo Naftowe I Gazownictwo Spółka Akcyjna.

Pipeline Construction Agreement” means that certain Pipeline Construction Agreement, dated as of January 23, 2019, by and between TCP and WHC, as amended by Change Order No. 1 dated June 13, 2019, Change Order No. 2 dated June 14, 2019, Change Order No. 3 dated July 19, 2019, Change Order No. 4 dated September 27, 2019, Change Order No. 5 dated as of April 9, 2020, Change Order No. 6 dated as of January 14, 2021, Change Order No. 7 dated as of January 27, 2021, Change Order No. 8, dated as of February 10, 2021, Change Order No. 9 dated as March 4, 2021, Change Order No. 10 dated March 26, 2021, and Change Order No. 11 dated June 9, 2021 and Amendment No. 1 to Pipeline Construction Agreement dated as of June 28, 2019.

Pipeline Service Agreements” has the meaning given in Schedule A of the CSAA.

PIS Purchase Order” means that certain Purchase Order Contract for the Sale of Power Island System, dated as of September 25, 2018, between the Company and BHGE, as amended by Change Order No. 1 dated June 24, 2019, Change Order No. 2 dated as of December 23, 2019, Letter Agreement dated June 24, 2019, Change Order No. 3 dated as of February 26, 2020, Change Order No. 4 dated as of April 27, 2020, Change Order No. 5 dated as of June 24, 2020, Change Order No. 6 dated as of December 29, 2020, Change Order No. 7 dated as of February 10, 2021, Change Order No. 8 dated as of March 24, 2021 and Software License Addendum dated as of December 9, 2020, Change Order No. 9 dated as of May 26, 2021, Change Order No. 10 dated as of June 30, 2021 and Change Order No. 11 dated as of June 30, 2021.

Pledge Agreement” is the pledge agreement, dated as of the Credit Facilities Closing Date, between Pledgor and Collateral Agent for the Secured Parties.

Pledgor” means Calcasieu Pass Pledgor, LLC, a limited liability company organized under the laws of the State of Delaware.

PPS Gas Agreement” has the meaning given in the definition of Permitted Pipeline Sale.

Pre-LNG Production System Fixed Amount” means an amount equal to $[***].

 

30


Pretreatment Contract” means that certain Engineering and Procurement Agreement, dated as of December 21, 2018, by and between the Company and UOP as amended by Amendment No. 1 dated as of June 28, 2019, Amendment No. 2 dated as of August 16, 2019, Change Order No. 1 dated as of September 11, 2019, Change Order No. 2 dated as of December 6, 2019, Change Order No. 3 dated June 11, 2020, Change Order No. 4 dated December 1, 2020, Change Order No. 5 dated as of March 24, 2021, Change Order No. 6, dated as of March 8, 2021, and Change Order No. 7, dated as of April 12, 2021, and supplemented with that certain Amended and Restated Natural Gas Integrated Pretreatment Block License Agreement, dated as of July 17, 2019, by and between the Company and UOP

Private Placement Legend” means (a) in the case of the Initial Notes, the legend set forth in Section 2.06(g)(1) and (b) in the case of any Additional Notes any legend required or permitted by Section 2.01(d).

Project Completion Date” means the date upon which all of the conditions set forth in Section 14.1 of the Common Terms Agreement have been either satisfied, or, in each case, waived by the requisite parties to the Intercreditor Agreement.

Project Completion Date Distribution” means an amount equal to the sum of (a) 25% of the amount remaining on deposit in the Contingency Reserve Account after giving effect to the application of clauses (ii)(A) through (ii)(D) of Section 14.2(c) of the Common Terms Agreement and the amounts available for distribution pursuant to clause (b) of this definition, plus (b) 100% of any Cash Flows of the Obligors received prior to the Project Completion Date that are deposited into the Pre-Completion Revenues Account.

“Project Costs” has the meaning given in Schedule A of the CSAA.

“Projected Fixed DSCR” means, unless otherwise provided in this Indenture (a) for purposes of Section 4.06 during the Calculation Period; and (b) for all other purposes, during the applicable period beginning no earlier than (i) the first Indenture Payment Date to occur after the ”facility substantial completion deadline” (as defined in the applicable engineering, procurement and/or construction contracts), or (ii) if the Commercial Operation Date with respect to all of the Foundation LNG SPAs has occurred, the first Indenture Payment Date to occur after the incurrence of Indebtedness, entering into of a Sharing Arrangement, commencement of an LNG SPA Mandatory Offer, or consummation of a merger, consolidation, conversion, continuance or sale, assignment, transfer, lease, conveyance or other disposition of assets, as applicable, the ratio of:

 

  (a)

in all cases other than Section 4.06:

 

  (i)

the Cash Flow Available for Debt Service projected for such period, provided that, Cash Flow is calculated solely to reflect (A) the fixed price component under applicable Qualifying LNG SPAs (or, in the case of Additional Senior Debt, Expansion Senior Debt or Replacement Senior Debt, the applicable Qualifying Indenture LNG SPAs), (B) expected interest and investment earnings paid to the Company, TCP and/or its respective Restricted Subsidiaries (other than, following a Permitted

 

31


Pipeline Sale, TCP and its Restricted Subsidiaries) during such period, (C) amounts expected to be paid to the Company, TCP and/or its respective Restricted Subsidiaries (other than, following a Permitted Pipeline Sale, TCP and its Restricted Subsidiaries) during such period as Business Interruption Insurance Proceeds and (D) the fixed expenses that could reasonably be expected to be incurred by the Company, TCP and/or its respective Restricted Subsidiaries (other than, following a Permitted Pipeline Sale, TCP and its Restricted Subsidiaries) if the Material Project Counterparties were not lifting any cargoes under the Qualifying LNG SPAs (or, in the case of Additional Senior Debt, Expansion Senior Debt or Replacement Senior Debt, the applicable Qualifying Indenture LNG SPAs); provided, that the “fixed price component” shall be the price component identified as such in the applicable LNG SPA or such other price component approved by the Intercreditor Agent (at any time when Loans or Senior Debt Commitments remain outstanding) as the fixed price component; to

 

  (ii)

Senior Debt Obligations projected to be paid in such period (taking into account Permitted Hedging Instruments) (other than (A) pursuant to voluntary prepayments or mandatory prepayments, (B) with respect to Senior Debt that has bullet maturities or balloon payments at maturity or scheduled principal payments in the final year prior to maturity, such balloon payments and such scheduled principal payments in such final year, (C) Working Capital Debt and any Debt Service payable thereunder, (D) LC Costs, (E) interest in respect of the Senior Debt paid prior to the end of the Term Loan Availability Period (or, if no Loans or Senior Debt Commitments remain outstanding, any debt service that was pre-funded by the incurrence of Permitted Senior Debt, one of the use of proceeds of which was expressly for this purpose), (F) under any Permitted Hedging Instruments in respect of interest rates, in each case paid prior to the end of the Term Loan Availability Period, and (G) net payable amounts under Permitted Hedging Instruments that are not in respect of interest rates); and

 

  (b)

in the case of Section 4.06:

 

  (i)

the Cash Flow Available for Debt Service projected for such period; to

 

  (ii)

Senior Debt Obligations projected to be paid in such period (other than (A) pursuant to voluntary prepayments or mandatory prepayments, (B) with respect to Senior Debt that has bullet maturities or balloon payments at maturity or scheduled principal payments in the final year prior to maturity, such balloon payments and such scheduled principal payments in such final year, (C) Working Capital Debt and any Debt Service payable thereunder, (D) LC Costs, (E) interest in respect of the Senior Debt paid prior to the end of the Term Loan Availability Period (or, if no Loans or Senior Debt Commitments remain outstanding, any debt service that was pre-funded by the incurrence of Permitted Senior Debt, one of the use of proceeds of which was expressly for this purpose), (F) under any Permitted Hedging Instruments in respect of interest rates, in each case paid prior to the end of the Term Loan Availability Period, and (G) net payable amounts under Permitted Hedging Instruments that are not in respect of interest rates).

 

32


Project Facilities” has the meaning given in Schedule A of the CSAA.

Project Property” has the meaning given in Schedule A of the CSAA.

Prudent Industry Practice” has the meaning given in Schedule A of the CSAA.

QIB” means a “qualified institutional buyer” as defined in Rule 144A.

Qualified Owner” has the meaning given in Schedule A of the CSAA.

Qualified Pipeline Operator” means any Person that, directly or indirectly through a Subsidiary or a controlled Affiliate, within the last five (5) years, is engaged in the business of procuring or transporting at least 1.0 Bcf of natural gas per day.

Qualified Pipeline Owner” means any Person that directly or through an affiliate, (i) is (or is a Subsidiary or a controlled Affiliate of) a Qualified Pipeline Operator, (ii) has engaged a Qualified Pipeline Operator to operate the TransCameron Pipeline, (iii) has engaged with one or more Affiliates of the Sponsor to operate the TransCameron Pipeline or (iv) has provided the Intercreditor Agent with a certificate from the Independent Engineer stating that such Person (or its designated operator) is qualified to operate the TransCameron Pipeline.

Qualified Transporter” has the meaning given in Schedule A of the CSAA.

Qualifying Indenture LNG SPAs: means, collectively the Qualifying LNG SPAs and Additional Qualifying LNG SPAs.

Qualifying Term” means (a) with respect to the Initial LNG SPAs, a term at least longer than the expected amortization term of the Initial Senior Debt, (b) with respect to any LNG SPA replacing an LNG SPA that was previously a Qualifying LNG SPA, a term at least as long as the remaining term of the Initial LNG SPA it is replacing and (c) with respect to any other Qualifying LNG SPA, the term of such LNG SPA used in the relevant Projected Fixed DSCR calculation when determining the quantum of Senior Debt that could be incurred based on the revenues projected to be generated under such LNG SPA.

Rating Reaffirmation” means, with respect to any matter under this Indenture requiring a Rating Reaffirmation, that any two Recognized Credit Rating Agencies that are then rating the Notes (or, if only one Recognized Credit Rating Agency is then rating the Notes, such agency) have considered the matter and confirmed that, if implemented (or if such matter is an Event of Default, if such event continued), they would reaffirm the then current rating or provide a more favorable rating.

Real Estate” has the meaning given in Schedule A of the CSAA.

Real Property Documents” has the meaning given in Schedule A of the CSAA.

 

33


Recognized Credit Rating Agency” means S&P, Fitch, Moody’s, or any successor to S&P, Fitch, Moody’s, so long as such agency is a “nationally recognized statistical rating organization” registered with the SEC.

Regulation S” means Regulation S promulgated under the Securities Act.

Regulation S Global Note” means a Regulation S Temporary Global Note or Regulation S Permanent Global Note, as appropriate.

Regulation S Permanent Global Note” means a permanent Global Note issued in accordance with the second paragraph of Section 2.01(c).

Regulation S Temporary Global Note” means a temporary Global Note issued in accordance with the first paragraph of Section 2.01(c).

Replacement Assets” means (a) non-current assets that will be used or useful in a Permitted Business or (b) substantially all the assets of a Permitted Business or a majority of the voting stock of any Person engaged in a Permitted Business that will become on the date of acquisition thereof a Restricted Subsidiary.

Repsol” means Repsol LNG Holding, S.A.

Required Capital Expenditures” has the meaning given in Schedule A of the CSAA.

Required Export Authorization” means with respect to a Required LNG SPA at any time, (a) the Non-FTA Authorization, (b) the FTA Authorization and (c) any other Export Authorization which the Company designates as a “Required Export Authorization” pursuant to this Indenture, to the extent that at such time, the volumes permitted to be exported under the FTA Authorization, the Non-FTA Authorization or such other Export Authorization, as the case may be, are required in order to enable the sale of such Required LNG SPA’s share of the then-applicable Base Committed Quantity of LNG in accordance with the terms of such Required LNG SPA. For the avoidance of doubt, the Non-FTA Authorization is a Required Export Authorization for each of the Initial LNG SPAs in effect on the Notes Issue Date and until otherwise determined in accordance with Section 4.21.

Required LNG SPA” means any of the Qualifying LNG SPAs required to be maintained as described in Section 4.29.

Requisite Secured Parties” means the requisite percentage of Senior Creditors required under the CSAA with respect to a specific Decision in order to make such Decision and provide the required instruction to the Collateral Agent.

Reserve Amount” means, as of any date, an amount necessary to pay principal and interest in respect of the Notes projected to be due and payable on the next Payment Date (assuming that no Event of Default will occur during such period) taking into account, with respect to interest, the amount of interest that would accrue on the aggregate principal amount of the Notes outstanding for the covered six month period; provided that (a) the Notes projected to be due and payable for purposes of this calculation shall not include any voluntary or mandatory prepayment; and (b) for

 

34


purposes of the calculation of the scheduled principal payments in respect of any Notes of any series, any scheduled principal or final balloon payments in respect of the Notes of any series in the final year prior to maturity shall not be taken into account and instead only the equivalent of the principal payment on the immediately preceding Payment Date for payment of principal prior to such payment shall be taken into account.

Responsible Officer”, means, when used with respect to the Trustee, any officer within the Corporate Trust Division - Corporate Finance Unit of the Trustee (or any successor division or unit of the Trustee) located at the Corporate Trust Office of the Trustee, who has direct responsibility for the administration of this Indenture and also means, in the case of Section 7.01(c)(2) and the second sentence of Section 7.05, any other officer to whom such matter is referred because of his knowledge of and familiarity with the particular subject.

Restricted Definitive Note” means a Definitive Note bearing the Private Placement Legend.

Restricted Global Note” means a Global Note bearing the Private Placement Legend.

Restricted Payment” means (a) any dividend or other distribution by the Company (in cash, property of the Company, securities, obligations, or other property) on, or other dividends or distributions on account of, or the setting apart of money for a sinking or other analogous fund for, or the purchase, redemption, retirement or other acquisition by the Company of, any portion of any membership interest in the Company and (b) all payments (in cash, property of the Company, securities, obligations, or other property) of principal of, interest on and other amounts with respect to, or other payments on account of, or the setting apart of money for a sinking or other analogous fund for, or the purchase, redemption, retirement or other acquisition by the Company of, any Indebtedness owed to Pledgor or any other Person party to a pledge agreement or any Affiliate thereof, including any Subordinated Debt. Restricted Payments shall not include (i) payments under the Service Agreements (which shall be paid in accordance with Section 4.7 of the CSAA), (ii) Permitted Payments (which shall be paid in accordance with Sections 4.5(b)(ii)(C) and/or 4.7 of the CSAA) and (iii) any of the payments in (a) or (b) above (whether in cash, securities, obligations or otherwise) made among any of the Obligors.

Restricted Period” means the 40-day distribution compliance period as defined in Regulation S.

Restricted Subsidiary” of a Person means any Subsidiary of such Person that is not an Unrestricted Subsidiary. As of the Notes Issue Date, neither the Company nor TCP has any Subsidiaries.

Revenue Account” has the meaning given in Schedule A of the CSAA.

Rule 144” means Rule 144 promulgated under the Securities Act.

Rule 144A” means Rule 144A promulgated under the Securities Act.

Rule 144A Global Note” means a Global Note issued in accordance with Section 2.01(c)(1)(A).

 

35


Rule 903” means Rule 903 promulgated under the Securities Act.

Rule 904” means Rule 904 promulgated under the Securities Act.

S&P” means Standard & Poor’s Ratings Services, a division of McGraw-Hill Financial, Inc., or any successor thereto.

Screened Affiliate” means any Affiliate of a noteholder (i) that makes investment decisions independently from such noteholder and any other Affiliate of such noteholder that is not a Screened Affiliate, (ii) that has in place customary information screens between it and such noteholder and any other Affiliate of such noteholder that is not a Screened Affiliate and such screens prohibit the sharing of information with respect to the Company or its Subsidiaries, (iii) whose investment policies are not directed by such noteholder or any other Affiliate of such noteholder that is acting in concert with such noteholder in connection with its investment in the Notes, and (iv) whose investment decisions are not influenced by the investment decisions of such noteholder or any other Affiliate of such noteholder that is acting in concert with such Holder in connection with its investment in the Notes.

SEC” means the U.S. Securities and Exchange Commission.

Secured Accounts” has the meaning given in Schedule A of the CSAA.

Secured Parties” means the Senior Creditors, the Senior Creditor Group Representatives, the Intercreditor Agent, the Collateral Agent and the Account Bank.

Securities Act” means the U.S. Securities Act of 1933, as amended.

Security Documents” means the CSAA and any other document, agreement, notice, mortgage, instrument or filing creating and/or perfecting any Lien required to be created or perfected by the CSAA or any other Finance Document and shall include the Pledge Agreement, any deed of trust or mortgage entered into pursuant to Section 3.2(f) of the CSAA, including the Mortgage, any Patent or Trademark security agreement entered into pursuant to Section 3.5(g) of CSAA, and any account control agreement (including the Control Agreements) entered into pursuant to Section 4.12(a) of the CSAA.

Security Enforcement Action” has the meaning given in Schedule A of the CSAA.

Security Interests” means the Liens created or purported to be created by or pursuant to the Security Documents.

Senior Creditor” means a provider of Senior Debt that benefits from the CSAA, including the Facility Lenders, any Senior Noteholders and each Hedging Bank that is party to, or accedes to, the CSAA.

Senior Creditor Group” has the meaning given in Schedule A of the CSAA.

Senior Creditor Group Representative” has the meaning given in Schedule A of the CSAA.

 

36


Senior Debt” has the meaning given in Schedule A of the CSAA.

Senior Debt Commitments” has the meaning given in Schedule A of the CSAA.

Senior Debt Instrument” has the meaning given in Schedule A of the CSAA.

Senior Debt Obligations” has the meaning given in Schedule A of the CSAA, provided that, for the avoidance of doubt, Senior Debt Obligations shall include the Company’s obligations to pay: (a) all principal, interest and premiums on the Notes; and (b) all commissions, fees, reimbursements, indemnities, prepayment premiums and other amounts payable to the Holders hereunder; in each case whether such obligations are present, future, actual or contingent and including the payment of amounts that would become due under the Senior Debt Instruments or the Permitted Senior Debt Hedging Instruments but for the operation of the automatic stay under Section 362(a) of the Bankruptcy Code.

Senior Facilities Debt Service Reserve Account” has the meaning given in Schedule A of the CSAA.

Senior Facilities Reserve Amount” has the meaning given in Schedule A of the CSAA.

Senior Noteholder” has the meaning given in Schedule A of the CSAA.

Senior Notes” means the notes to be issued (or Facility Agreement to be entered into in the case of a “term loan B” financing that the Company has elected to be treated as an Indenture) pursuant to any Indenture.

Service Agreements” means:

 

  (a)

the Operation and Maintenance Agreement relating to the LNG Export and Liquefaction Facility to be located at the Calcasieu Pass Site in Cameron Parish, Louisiana, dated as of August 9, 2019, by and between the Company and Calcasieu Pass Operations, LLC;

 

  (b)

the Administrative Services Agreement relating to the LNG Export and Liquefaction Facility to be located at the Calcasieu Pass Site in Cameron Parish, Louisiana, dated as of July 9, 2019, by and between the Company and Venture Global Services, LLC;

 

  (c)

the Pipeline Operation and Maintenance Agreement relating to the TransCameron Natural Gas Pipeline dated as of August 9, 2019, by and between TCP and TransCameron Operations, LLC;

 

  (d)

the Administrative Services Agreement relating to the TransCameron Natural Gas Pipeline, dated as of July 9, 2019, by and between TCP and Venture Global Services, LLC;

 

  (e)

the long-term service agreement to be entered into by and between the Company and BHGE;

 

37


  (f)

the Field Services Agreement, dated as of August 14, 2019, by and between the Company and BHGE; and

 

  (g)

the Technical Advisor Services Agreement, dated as of July 29, 2019, by and between the Company and UOP.

Shell” means Shell NA LNG LLC.

Short Derivative Instruments” means, as to any person, a Derivative Instrument (i) the value of which to such person generally decreases, and/or the payment or delivery obligations of such person under which generally increase, with positive changes in the financial performance and/or position of the Company and/or (ii) the value of which to such person generally increases, and/or the payment or delivery obligations of such person under which generally decrease, with negative changes in the financial performance and/or position of the Company.

Specified Counterparty” means (a) prior to the Project Completion Date, each of the Construction Contractors and each guarantor party to a Parent Guarantee, (b) any counterparty to a Required LNG SPA, (c) any guarantor party to an Initial LNG SPA Guarantee or any other guarantee delivered in respect of a Required LNG SPA and (d) after a Permitted Pipeline Sale, any counterparty to a PPS Gas Agreement and any guarantor party to a guarantee delivered in respect of a PPS Gas Agreement.

Sponsor” means Venture Global LNG, Inc., a corporation organized under the laws of the State of Delaware.

State of New York,” “New York” or “NY” means the State of New York in the United States.

Storage Tanks EPC Contract” means that certain Amended and Restated LNG Storage Tanks Engineering, Procurement and Construction Agreement, dated as of December 22, 2017, by and between CB&I and the Company, as amended by Amendment No. 1 to Amended and Restated LNG Storage Tanks Engineering, Procurement and Construction Agreement dated as of April 1, 2019, Amendment No. 2 to Amended and Restated LNG Storage Tanks Engineering, Procurement and Construction Agreement dated as of June 30, 2019, Change Order No. 1, dated as of December 17, 2019, Change Order No. 2, dated as of December 24, 2019, Change Order No. 3, dated as of December 30, 2019, Change Order No. 4 dated as of June 9, 2020, Change Order No. 05 dated as of October 6, 2020, Change Order No. 06, dated as of October 20, 2020, Change Order No. 07, dated as of April 12, 2021, and Change Order No. 8, dated as of May 27, 2021.

Storm Surge Wall Construction Agreement” means that certain Construction Agreement relating to a Storm Surge Wall, dated as of February 15, 2017, by and between the Company and Weeks Marine, as amended by Amendment No. 1 to Construction Agreement, dated as of December 13, 2017, Amendment No. 2 to Construction Agreement, dated as October 5, 2018, Amendment No. 3 to Construction Agreement, dated as of March 5, 2019, Amendment No. 4 to Construction Agreement, dated as of June 28, 2019, and Amendment No. 5 to Construction Agreement, dated as of December 12, 2019, Change Order No. 1, dated September 27, 2019, between the Company and Weeks Marine (Storm Surge Wall) and Change Order No. 2 dated February 26, 2020, and Change Order No. 3 dated June 15, 2020.

 

38


Subordinated Debt” means any unsecured debt or obligation that ranks subordinate in right of payment to the Notes on the basis set forth in a subordination agreement in a form attached to the Common Terms Agreement, and if no Loans or Senior Debt Commitments in connection therewith remain outstanding, in the form attached to this Indenture.

Subsequent Material Project Agreements” has the meaning given in Schedule A of the CSAA.

Subsidiary” has the meaning given in Schedule A of the CSAA.

Supplemental Indenture” means any indenture supplemental to this Indenture governing the terms and conditions of any Additional Notes issued from time to time pursuant to Section 2.01(d), in each case, to the extent that the Indebtedness evidenced by any Additional Notes, and the terms and conditions of any such Indebtedness, Additional Notes and Supplemental Indenture, are permitted by this Indenture, including Article 4.

Supplemental Quantity” has the meaning given in Schedule A of the CSAA.

Taxes” has the meaning given in Schedule A of the CSAA.

Term Lenders” means those Term Lenders identified on Schedule I of the Credit Facility Agreement and each other Person that acquires the rights and obligations of any such Term Lender in accordance with the Credit Facility Agreement but excluding any Person that has assigned all of its rights and obligations under the Credit Facility Agreement (other than in connection with the sale of participations) and Loan Participants.

Term Loan Availability Period” means the period commencing (solely with respect to the initial advance under the Credit Facility Agreement) on the Credit Facilities Closing Date and (with respect to all other advances of Term Loans) following the utilization in full of both the Closing Date Equity Funding and the initial advance under the Credit Facility Agreement, and ending on the earliest of:

 

  (a)

the Date Certain;

 

  (b)

the Project Completion Date;

 

  (c)

the date the Term Loan Commitments are fully utilized or of any cancellation or termination of all of the remaining Term Loan Commitments pursuant the Common Terms Agreement; and

 

  (d)

the date the required lenders under the Credit Facility Agreement terminate their commitments under the Credit Facility Agreement upon the occurrence and during the Continuance of a Loan Facility Event of Default.

Term Loan Commitment” has the meaning given in Schedule A of the CSAA.

TIA” means the Trust Indenture Act of 1939, as amended.

 

39


Title Policy” has the meaning given in Schedule A of the CSAA.

Transaction Documents” means, collectively, the Finance Documents and the Material Project Agreements.

TransCameron Pipeline” has the meaning given in Schedule A of the CSAA.

Trustee” means The Bank of New York Mellon Trust Company, N.A. until a successor replaces it in accordance with the applicable provisions of this Indenture and thereafter means the successor serving hereunder.

Unmatured Event of Default” means an event that, with the giving of notice, lapse of time or making of a determination, would constitute an Event of Default.

Unmatured Loan Facility Event of Default” has the meaning given in Schedule A of the CSAA.

United States” or “U.S.” means the United States of America.

Unrestricted Definitive Note” means a Definitive Note that does not bear and is not required to bear the Private Placement Legend.

Unrestricted Global Note” means a Global Note that does not bear and is not required to bear the Private Placement Legend.

Unrestricted Subsidiary” means any Subsidiary of the Company or TCP that is designated by the Board of Directors (or equivalent governing body) of the Company or TCP, respectively, as an Unrestricted Subsidiary pursuant to a resolution of the Board of Directors (or equivalent governing body), but only to the extent that such Subsidiary:

 

  (a)

has no Indebtedness other than Non-Recourse Debt;

 

  (b)

except as permitted in Section 4.13, is not party to any agreement, contract, arrangement or understanding with the Company, TCP or any of their Restricted Subsidiaries unless the terms of any such agreement, contract, arrangement or understanding are no less favorable to the Company, TCP or such Restricted Subsidiary than those that might be obtained at the time from Persons who are not Affiliates of the Company or TCP;

 

  (c)

is a Person with respect to which none of the Company, TCP and any of their Restricted Subsidiaries has any direct or indirect obligation (i) to subscribe for additional Equity Interests or (ii) to maintain or preserve such Person’s financial condition or to cause such Person to achieve any specified levels of operating results; and

 

  (d)

has not guaranteed or otherwise directly or indirectly provided credit support for any Indebtedness of the Company, TCP or any of their Restricted Subsidiaries.

 

40


UOP” means UOP LLC.

U.S. Person” means a U.S. Person as defined in Rule 902(k) promulgated under the Securities Act.

Weeks Marine” means Weeks Marine, Inc. “WHC” means WHC, LLC

Working Capital Debt” means senior secured or unsecured Indebtedness (which, if secured, shall constitute Senior Debt), under one or more working capital facilities, for working capital purposes (including in the forms of undrawn commitments, outstanding indebtedness and the issuance of letters of credit from time to time).

Section 1.02 Other Definitions.

 

Term

   Defined
in Section
 

“2029 Call Date”

     3.07  

“2029 Make-Whole Price”

     3.07  

“2031 Make-Whole Price”

     3.07  

“2031 Call Date”

     3.07  

“Accession Agreement”

     10.02  

“Additional Senior Debt”

     4.09  

“Applicable Expansion Debt Assets”

     4.09  

“Applicable Tax Law”

     7.02  

“Asset Sale Offer”

     3.09  

“Authentication Order”

     2.02  

“Cessation Notice”

     6.04  

“Change of Control Offer”

     4.17  

“Change of Control Payment”

     4.17  

“Change of Control Payment Date”

     4.17  

“Court Determination”

     6.05  

“Covenant Defeasance”

     8.03  

“Declared Event of Default”

     6.02  

“Directing Holder”

     6.05  

“DTC”

     2.03  

“Event of Default”

     6.01  

“Excess Loss Proceeds Offer”

     3.09  

“Excess Loss Proceeds”

     4.19  

“Excess Proceeds”

     4.12  

“Expansion”

     4.11  

“Expansion Equity Funding Commitment”

     4.11  

 

41


Term

   Defined
in Section
 

Expansion Senior Debt

     4.09  

Export Authorization Remediation

     4.21  

Fundamental Modification

     9.03  

Indenture LNG SPA Prepayment Event

     4.21  

Indenture Payment Default

     6.01  

Initial Series Notes

     3.07  

Instructing Officers

     13.02  

Instructions

     13.02  

Legal Defeasance

     8.02  

LNG SPA Mandatory Offer

     3.09  

LNG SPA Mandatory Prepayment Amount (CTA Calculation)

     4.21  

LNG SPA Mandatory Prepayment Amount (CTA/Indenture Calculation)

     4.21  

LNG SPA Mandatory Offer Amount

     4.21  

Noteholder Direction

     6.05  

Offer Amount

     3.09  

Offer Period

     3.09  

Paying Agent

     2.03  

PDE Senior Debt”

     4.09  

PLD Excess Proceeds

     4.20  

PLD Excess Proceeds Offer

     3.09  

Position Representation

     6.05  

Purchase Date

     3.09  

Qualifying LNG SPA

     4.29  

Registrar

     2.03  

Replacement Indenture Qualifying LNG SPA

     4.29  

Replacement Senior Debt

     4.09  

Reversion Date

     4.45  

Rule 144A Information

     4.03  

Sharing Arrangement

     4.28  

Successor Guarantor

     11.04  

Treasury Rate

     3.07  

Verification Covenant

     6.05  

 

42


Section 1.03 Rules of Construction.

 

  (a)

Unless the context otherwise requires:

(1) the table of contents and headings are for convenience only and shall not affect the interpretation of the Indenture;

(2) unless otherwise specified, references to articles, sections, clauses, appendices, exhibits, schedules or annexes are references to articles, sections, clauses, appendices, exhibits, schedules or annexes to this Indenture;

(3) references to any party to this Indenture or any other document or agreement shall include its successors and permitted transferees and assigns;

(4) an “authorization” includes an authorization, consent, approval, resolution, license, exemption, filing, registration and notarization;

(5) “law” shall be construed as any law (including common or customary law), statute, constitution, decree, judgment, treaty, regulation, directive, by-law, order, ordinance or any other legislative measure of any government, supranational, local government, statutory or regulatory body or court, in each case having the force of law;

(6) unless as otherwise provided, any reference to assignment of a person’s rights and/or obligations shall be construed to refer to assignment, transfer or novation of those rights and/or obligations;

(7) any reference to the actions or omissions of agents, representatives or authorized persons shall refer only to actions or omissions taken in connection with the agency, representation or authorization;

(8) the omission of the word “any” or the phrase “if any” with respect to anything shall not imply that the thing exists or is required, notwithstanding the inclusion of such word or phrase (for clarity) in other provisions;

(9) any reference to an action being taken “pursuant to” an agreement or document, or any specified provision thereof, shall be construed to mean “pursuant to and in compliance with” the requirements of such agreement, document or provision;

(10) in some instances, a word or reference that, pursuant to these rules of interpretation, is not necessary (for example, inclusion of both the singular and plural), may be included for emphasis or clarity, and any such usage shall not give rise to any negative implication in relation to any other usage, which other usage shall nonetheless be interpreted strictly in accordance with the rules of interpretation set forth herein;

(11) a term has the meaning assigned to it;

(12) an accounting term not otherwise defined has the meaning assigned to it in accordance with GAAP;

(13) “or” is not exclusive;

(14) “including” means “including without limitation” whether or not stated;

 

43


(15) words in the singular include the plural, and in the plural include the singular;

(16) “will” shall be interpreted to express a command and shall be construed to have the same meaning and effect as the word “shall”;

(17) provisions apply to successive events and transactions;

(18) references to sections of or rules under the Securities Act will be deemed to include substitute, replacement of successor sections or rules adopted by the SEC from time to time; and

(19) references to any document, agreement or instrument means such document, agreement or instrument as it may be amended, amended and restated or otherwise modified in accordance with its terms.

(b) Any references herein to “this Indenture,” is a reference to this indenture as described in the first paragraph hereof. References in this Indenture to “an Indenture,” “any Indenture,” or “the Indenture” and to “Senior Notes” and “the Senior Notes,” are references to the defined terms “Indenture” and “Senior Notes” in the CSAA. For purposes of the CSAA, this Indenture is an “Indenture,” and the Notes will be “Senior Notes.”

ARTICLE 2

THE NOTES

Section 2.01 Form and Dating.

(a) General. The terms and provisions contained in the Notes will constitute, and are hereby expressly made, a part of this Indenture and the Company, the Guarantors and the Trustee, by their execution and delivery of this Indenture, expressly agree to such terms and provisions and to be bound thereby. However, to the extent any provision of any Note conflicts with the express provisions of this Indenture, the provisions of this Indenture shall govern and be controlling.

(b) Global Notes. Except as otherwise provided in this Section 2.01, Notes issued in global form (and the Trustee’s certificate of authentication of such Notes) will be substantially in the form of Exhibit A-1, A-2, A-3 or A-4 (including the Global Note Legend thereon and the “Schedule of Exchanges of Interests in the Global Note” attached thereto). Each such Note will be dated the date of its authentication. Except as otherwise provided in this Section 2.01, Notes issued in definitive form will be substantially in the form of Exhibit A-1 and A-3 (but without the Global Note Legend thereon and without the “Schedule of Exchanges of Interests in the Global Note” attached thereto) in an aggregate denomination equal to (i) in the case of the 2029 Notes, $1,250,000,000 and (ii) in the case of the 2031 Notes, $1,250,000,000 and (iii) in the case of any Additional Notes the aggregate initial principal amount of such Notes. Each Global Note will represent such of the outstanding Notes as will be specified therein and each shall provide that it represents the aggregate principal amount of outstanding Notes from time to time endorsed thereon and that the aggregate principal amount of outstanding Notes represented thereby may from time to time be reduced or increased, as appropriate, to reflect exchanges and redemptions. Any

 

44


endorsement of a Global Note to reflect the amount of any increase or decrease in the aggregate principal amount of outstanding Notes represented thereby will be made by the Trustee or the Custodian, at the direction of the Trustee, in accordance with instructions given by the Holder thereof as required by Section 2.06.

(c) Temporary Global Notes. Notes offered and sold in reliance on Regulation S will be issued in a denomination equal to the outstanding principal amount of such Notes initially in the form of Exhibit A-2 or A-4. Such Notes will be deposited on behalf of the purchasers of the Notes represented thereby with or on behalf of, and registered in the name of, the Depositary or the nominee of the Depositary for the accounts of designated agents holding on behalf of Euroclear or Clearstream, duly executed by the Company and authenticated by the Trustee as hereinafter provided. The Restricted Period will be terminated upon the receipt by the Trustee of:

(1) a written certificate from the Depositary, together with copies of certificates from Euroclear and Clearstream certifying that they have received certification of non- United States beneficial ownership of 100% of the aggregate principal amount of the Regulation S Temporary Global Note (except to the extent of any beneficial owners thereof who acquired an interest therein during the Restricted Period pursuant to another exemption from registration under the Securities Act and who will take delivery of a beneficial ownership interest in (A) a Global Note substantially in the form of Exhibit A-1 or A-3, bearing the Global Note Legend and the Private Placement Legend, deposited with or on behalf of, and registered in the name of, the Depositary or its nominee, and issued in a denomination equal to the outstanding principal amount of the Notes sold in reliance on Rule 144A or (B) a Global Note bearing the Global Note Legend and the Private Placement Legend, deposited with or on behalf of, and registered in the name of, the Depositary or the nominee of the Depositary, and issued in a denomination equal to the outstanding principal amount of Notes sold to Institutional Accredited Investors), all as contemplated by Section 2.06(b) hereof; and

(2) an Officer’s Certificate from the Company.

Following the termination of the Restricted Period with respect to any Notes, beneficial interests in the Regulation S Temporary Global Note will be exchanged, pursuant to the Applicable Procedures, for beneficial interests in a permanent Global Note, which will be in the form of Exhibit A-1 or A-3 bearing the Global Note Legend and the Private Placement Legend, deposited with or on behalf of, and registered in the name of, the Depositary or the nominee of the Depositary, and issued in a denomination equal to the outstanding principal amount of the Regulation S Temporary Global Note upon expiration of the Restricted Period. Simultaneously with the authentication of the Regulation S Permanent Global Note, the Trustee will cancel the Regulation S Temporary Global Note. The aggregate principal amount of the Regulation S Temporary Global Note and the Regulation S Permanent Global Note may from time to time be increased or decreased by adjustments made on the records of the Trustee and the Depositary or its nominee, as the case may be, in connection with transfers of interest as hereinafter provided.

 

45


(3) Euroclear and Clearstream Procedures Applicable. The provisions of the “Operating Procedures of the Euroclear System” and “Terms and Conditions Governing Use of Euroclear” and the “General Terms and Conditions of Clearstream Banking” and “Customer Handbook” of Clearstream will be applicable to transfers of beneficial interests in the Regulation S Temporary Global Note and the Regulation S Permanent Global Note that are held by Participants through Euroclear or Clearstream.

(d) Additional Notes. Subject to compliance with the provisions of this Indenture, the Company may from time to time after the Notes Issue Date issue Additional Notes as provided in Exhibit F, which is incorporated by reference in this Section 2.01(d).

Section 2.02 Execution and Authentication.

At least one Authorized Officer must sign the Notes for the Company by manual or electronic signature.

If an Authorized Officer whose signature is on a Note no longer holds that office at the time a Note is authenticated, the Note will nevertheless be valid.

A Note will not be valid until authenticated by the manual or electronic signature of the Trustee. The signature will be conclusive evidence that the Note has been authenticated under this Indenture.

The Trustee will, upon receipt of a written order of the Company signed by at least one Authorized Officer (an “Authentication Order”), authenticate Notes for original issue that may be validly issued under this Indenture, including any Additional Notes. The aggregate principal amount of Notes outstanding at any time may not exceed the aggregate principal amount of Notes authorized for issuance by the Company pursuant to one or more Authentication Orders, except as provided in Section 2.07.

The Trustee may appoint an authenticating agent acceptable to the Company to authenticate Notes. An authenticating agent may authenticate Notes whenever the Trustee may do so. Each reference in this Indenture to authentication by the Trustee includes authentication by such agent. An authenticating agent has the same rights as an Agent to deal with Holders or an Affiliate of the Company.

The Initial Notes and the Additional Notes shall be treated as a single class for all purposes under this Indenture, and unless the context otherwise requires, all references to the Notes shall include the Initial Notes and any Additional Notes. Nothing in this paragraph shall be deemed to modify, replace or otherwise affect the restrictions on transfer applicable to Restricted Notes set forth in Section 2.06.

Section 2.03 Registrar and Paying Agent; Depositary.

The Company will maintain an office or agency where Notes may be presented for registration of transfer or for exchange (“Registrar”) and an office or agency where Notes may be presented for payment (“Paying Agent”). The Registrar will keep a register of the Notes and of their transfer and exchange. The Company may appoint one or more co-registrars and one or more additional paying agents. The term “Registrar” includes any co-registrar and the term “Paying Agent” includes any additional paying agent. The Company may change any Paying Agent or Registrar without notice to any Holder. The Company will notify the Trustee in writing of the name and address of any Agent not a party to this Indenture. If the Company fails to appoint or maintain another entity as Registrar or Paying Agent, the Trustee shall act as such. The Company or any of its Subsidiaries may act as Paying Agent or Registrar.

 

46


The Company initially appoints The Depository Trust Company (“DTC”) to act as Depositary with respect to the Global Notes.

The Company initially appoints the Trustee to act as the Registrar and Paying Agent and to act as Custodian with respect to the Global Notes.

Section 2.04 Paying Agent to Hold Money in Trust.

The Company will require each Paying Agent other than the Trustee to agree in writing that the Paying Agent will hold in trust for the benefit of Holders or the Trustee all money held by the Paying Agent for the payment of principal, premium, or interest on the Notes, and will notify the Trustee of any default by the Company in making any such payment. While any such default continues, the Trustee may require a Paying Agent to pay all money held by it to the Trustee. The Company at any time may require a Paying Agent to pay all money held by it to the Trustee. Upon payment over to the Trustee, the Paying Agent (if other than the Company or a Subsidiary) will have no further liability for the money. If the Company or a Subsidiary acts as Paying Agent, it will segregate and hold in a separate trust fund for the benefit of the Holders all money held by it as Paying Agent. Upon any bankruptcy or reorganization proceedings relating to the Company, the Trustee will serve as Paying Agent for the Notes.

Section 2.05 Holder Lists.

The Trustee will preserve in as current a form as is reasonably practicable the most recent list available to it of the names and addresses of all Holders. If the Trustee is not the Registrar, the Company on its own behalf and on behalf of the Guarantors will furnish to the Trustee at least seven Business Days before each Interest Payment Date and at such other times as the Trustee may request in writing, a list in such form and as of such date as the Trustee may reasonably require of the names and addresses of the Holders.

Section 2.06 Transfer and Exchange.

(a) Transfer and Exchange of Global Notes. A Global Note may not be transferred except as a whole by the Depositary to a nominee of the Depositary, by a nominee of the Depositary to the Depositary or to another nominee of the Depositary, or by the Depositary or any such nominee to a successor Depositary or a nominee of such successor Depositary. All Global Notes will be exchanged by the Company for Definitive Notes if:

(1) the Company delivers to the Trustee notice from the Depositary that it is unwilling or unable to continue to act as Depositary for the Global Notes or that it has ceased to be a clearing agency registered under the Exchange Act and, in either case, a successor Depositary is not appointed by the Company within 120 days after the date of such notice from the Depositary;

 

47


(2) the Company, at its option, determines that the Global Notes (in whole but not in part) should be exchanged for Definitive Notes and delivers a written notice to such effect to the Trustee; provided that in no event shall the Regulation S Temporary Global Note be exchanged by the Company for Definitive Notes prior to (A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903(b)(3)(ii)(B) under the Securities Act; or

(3) there has occurred and is Continuing an Event of Default with respect to the Notes.

Upon the occurrence of either of the preceding events in (1) or (2) above, Definitive Notes shall be issued in such names as the Depositary shall instruct the Trustee. Global Notes also may be exchanged or replaced, in whole or in part, as provided in Sections 2.07 and 2.10. Every Note authenticated and delivered in exchange for, or in lieu of, a Global Note or any portion thereof, pursuant to this Section 2.06 or Sections 2.07 or 2.10, shall be authenticated and delivered in the form of, and shall be, a Global Note. A Global Note may not be exchanged for another Note other than as provided in this Section 2.06(a), however, beneficial interests in a Global Note may be transferred and exchanged as provided in Section 2.06(b) or (c) or.

(b) Transfer and Exchange of Beneficial Interests in the Global Notes. The transfer and exchange of beneficial interests in the Global Notes will be effected through the Depositary, in accordance with the provisions of this Indenture and the Applicable Procedures. Beneficial interests in the Restricted Global Notes will be subject to restrictions on transfer comparable to those set forth herein to the extent required by the Securities Act. Transfers of beneficial interests in the Global Notes also will require compliance with either subparagraph (1) or (2) below, as applicable, as well as one or more of the other following subparagraphs, as applicable:

(1) Transfer of Beneficial Interests in the Same Global Note. Beneficial interests in any Restricted Global Note may be transferred to Persons who take delivery thereof in the form of a beneficial interest in the same Restricted Global Note in accordance with the transfer restrictions set forth in the Private Placement Legend; provided, however, that prior to the expiration of the Restricted Period, transfers of beneficial interests in the Regulation S Temporary Global Note may not be made to a U.S. Person or for the account or benefit of a U.S. Person (other than the Initial Purchasers of the Notes). Beneficial interests in any Unrestricted Global Note may be transferred to Persons who take delivery thereof in the form of a beneficial interest in an Unrestricted Global Note. No written orders or instructions shall be required to be delivered to the Registrar to effect the transfers described in this Section 2.06(b)(1).

(2) All Other Transfers and Exchanges of Beneficial Interests in Global Notes. In connection with all transfers and exchanges of beneficial interests that are not subject to Section 2.06(b)(1), the transferor of such beneficial interest must deliver to the Registrar either:

(A) both:

 

48


(i) a written order from a Participant or an Indirect Participant given to the Depositary in accordance with the Applicable Procedures directing the Depositary to credit or cause to be credited a beneficial interest in another Global Note in an amount equal to the beneficial interest to be transferred or exchanged; and

(ii) instructions given in accordance with the Applicable Procedures containing information regarding the Participant account to be credited with such increase; or

(B) both:

(i) a written order from a Participant or an Indirect Participant given to the Depositary in accordance with the Applicable Procedures directing the Depositary to cause to be issued a Definitive Note in an amount equal to the beneficial interest to be transferred or exchanged; and

(ii) instructions given by the Depositary to the Registrar containing information regarding the Person in whose name such Definitive Note shall be registered to effect the transfer or exchange referred to in (1) above;

provided that in no event shall Definitive Notes be issued upon the transfer or exchange of beneficial interests in the Regulation S Temporary Global Note prior to (A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903 under the Securities Act.

Upon satisfaction of all of the requirements for transfer or exchange of beneficial interests in Global Notes contained in this Indenture and the Notes or otherwise applicable under the Securities Act, the Trustee shall adjust the principal amount of the relevant Global Note(s) pursuant to Section 2.06(h).

(3) Transfer of Beneficial Interests to Another Restricted Global Note. A beneficial interest in any Restricted Global Note may be transferred to a Person who takes delivery thereof in the form of a beneficial interest in another Restricted Global Note if the transfer complies with the requirements of Section 2.06(b)(2) and the Registrar receives the following:

(A) if the transferee will take delivery in the form of a beneficial interest in the Rule 144A Global Note, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (1) thereof;

(B) if the transferee will take delivery in the form of a beneficial interest in the Regulation S Temporary Global Note or the Regulation S Permanent Global Note, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (2) thereof; and

 

49


(C) if the transferee will take delivery in the form of a beneficial interest in the IAI Global Note, then the transferor must deliver a certificate in the form of Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable.

(4) Transfer and Exchange of Beneficial Interests in a Restricted Global Note for Beneficial Interests in an Unrestricted Global Note. A beneficial interest in any Restricted Global Note may be exchanged by any Holder thereof for a beneficial interest in an Unrestricted Global Note or transferred to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note if the exchange or transfer complies with the requirements of Section 2.06(b)(2) and the Registrar receives the following:

(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a beneficial interest in an Unrestricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(a) thereof; or

(B) if the Holder of such beneficial interest in a Restricted Global Note proposes to transfer such beneficial interest to a Person who shall take delivery thereof in the form of a beneficial interest in an Unrestricted Global Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof; and, in each such case set forth in this clause (4), if the Registrar so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Company to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

If any such transfer is effected pursuant to this clause (4) at a time when an Unrestricted Global Note has not yet been issued, the Company shall issue and, upon receipt of an Authentication Order in accordance with Section 2.02, the Trustee shall authenticate one or more Unrestricted Global Notes in an aggregate principal amount equal to the aggregate principal amount of beneficial interests transferred pursuant to this clause (4) .

Beneficial interests in an Unrestricted Global Note cannot be exchanged for, or transferred to Persons who take delivery thereof in the form of, a beneficial interest in a Restricted Global Note.

(c) Transfer or Exchange of Beneficial Interests for Definitive Notes.

(1) Beneficial Interests in Restricted Global Notes to Restricted Definitive Notes. If any Holder of a beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a Restricted Definitive Note or to transfer such beneficial interest to a Person who takes delivery thereof in the form of a Restricted Definitive Note, then, upon receipt by the Registrar of the following documentation:

 

50


(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a Restricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (2)(a) thereof;

(B) if such beneficial interest is being transferred to a QIB in accordance with Rule 144A, a certificate to the effect set forth in Exhibit B, including the certifications in item (1) thereof;

(C) if such beneficial interest is being transferred to a Non-U.S. Person in an offshore transaction in accordance with Rule 903 or Rule 904, a certificate to the effect set forth in Exhibit B, including the certifications in item (2) thereof;

(D) if such beneficial interest is being transferred pursuant to an exemption from the registration requirements of the Securities Act in accordance with Rule 144, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(a) thereof;

(E) if such beneficial interest is being transferred to an Institutional Accredited Investor in reliance on an exemption from the registration requirements of the Securities Act other than those listed in subparagraphs (B) through (D) above, a certificate to the effect set forth in Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable;

(F) if such beneficial interest is being transferred to the Company or any of its Subsidiaries, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(b) thereof; or

(G) if such beneficial interest is being transferred pursuant to an effective registration statement under the Securities Act, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(c) thereof,

the Trustee shall cause the aggregate principal amount of the applicable Global Note to be reduced accordingly pursuant to Section 2.06(h), and the Company shall execute and the Trustee shall authenticate and deliver to the Person designated in the instructions a Definitive Note in the appropriate principal amount. Any Definitive Note issued in exchange for a beneficial interest in a Restricted Global Note pursuant to this Section 2.06(c) shall be registered in such name or names and in such authorized denomination or denominations as the Holder of such beneficial interest shall instruct the Registrar through instructions from the Depositary and the Participant or Indirect Participant. The Trustee shall deliver such Definitive Notes to the Persons in whose names such Notes are so registered. Any Definitive Note issued in exchange for a beneficial interest in a Restricted Global Note pursuant to this Section 2.06(c)(1) shall bear the Private Placement Legend and shall be subject to all restrictions on transfer contained therein.

(2) Beneficial Interests in Regulation S Temporary Global Note to Definitive Notes. Notwithstanding Sections 2.06(c)(1)(A) and (C), a beneficial interest in the Regulation S Temporary Global Note may not be exchanged for a Definitive Note or transferred to a Person who takes delivery thereof in the form of a Definitive Note prior to

 

51


(A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903(b)(3)(ii)(B) under the Securities Act, except in the case of a transfer pursuant to an exemption from the registration requirements of the Securities Act other than Rule 903 or Rule 904.

(3) Beneficial Interests in Restricted Global Notes to Unrestricted Definitive Notes. A Holder of a beneficial interest in a Restricted Global Note may exchange such beneficial interest for an Unrestricted Definitive Note or may transfer such beneficial interest to a Person who takes delivery thereof in the form of an Unrestricted Definitive Note only if the Registrar receives the following:

(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(b) thereof; or

(B) if the Holder of such beneficial interest in a Restricted Global Note proposes to transfer such beneficial interest to a Person who shall take delivery thereof in the form of an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

and, in each such case set forth in this clause (3), if the Registrar so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Company to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

(4) Beneficial Interests in Unrestricted Global Notes to Unrestricted Definitive Notes. If any Holder of a beneficial interest in an Unrestricted Global Note proposes to exchange such beneficial interest for a Definitive Note or to transfer such beneficial interest to a Person who takes delivery thereof in the form of a Definitive Note, then, upon satisfaction of the conditions set forth in Section 2.06(b)(2), the Trustee will cause the aggregate principal amount of the applicable Global Note to be reduced accordingly pursuant to Section 2.06(h), and the Company will execute and the Trustee will authenticate and deliver to the Person designated in the instructions a Definitive Note in the appropriate principal amount. Any Definitive Note issued in exchange for a beneficial interest pursuant to this Section 2.06(c)(4) will be registered in such name or names and in such authorized denomination or denominations as the Holder of such beneficial interest requests through instructions to the Registrar from or through the Depositary and the Participant or Indirect Participant. The Trustee will deliver such Definitive Notes to the Persons in whose names such Notes are so registered. Any Definitive Note issued in exchange for a beneficial interest pursuant to this Section 2.06(c)(4) will not bear the Private Placement Legend.

(d) Transfer and Exchange of Definitive Notes for Beneficial Interests.

 

52


(1) Restricted Definitive Notes to Beneficial Interests in Restricted Global Notes. If any Holder of a Restricted Definitive Note proposes to exchange such Note for a beneficial interest in a Restricted Global Note or to transfer such Restricted Definitive Notes to a Person who takes delivery thereof in the form of a beneficial interest in a Restricted Global Note, then, upon receipt by the Registrar of the following documentation:

(A) if the Holder of such Restricted Definitive Note proposes to exchange such Note for a beneficial interest in a Restricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (2)(b) thereof;

(B) if such Restricted Definitive Note is being transferred to a QIB in accordance with Rule 144A, a certificate to the effect set forth in Exhibit B, including the certifications in item (1) thereof;

(C) if such Restricted Definitive Note is being transferred to a Non-U.S. Person in an offshore transaction in accordance with Rule 903 or Rule 904, a certificate to the effect set forth in Exhibit B, including the certifications in item (2) thereof;

(D) if such Restricted Definitive Note is being transferred pursuant to an exemption from the registration requirements of the Securities Act in accordance with Rule 144, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(a) thereof;

(E) if such Restricted Definitive Note is being transferred to an Institutional Accredited Investor in reliance on an exemption from the registration requirements of the Securities Act other than those listed in subparagraphs (B) through (D) above, a certificate to the effect set forth in Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable;

(F) if such Restricted Definitive Note is being transferred to the Company or any of its Subsidiaries, a certificate to the effect set forth in Exhibit B hereto, including the certifications in item (3)(b) thereof; or

(G) if such Restricted Definitive Note is being transferred pursuant to an effective registration statement under the Securities Act, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(c) thereof,

the Trustee will cancel the Restricted Definitive Note, increase or cause to be increased the aggregate principal amount of, in the case of clause (A) above, the appropriate Restricted Global Note, in the case of clause (B) above, the Rule 144A Global Note, in the case of clause (C) above, the Regulation S Global Note, in the case of clause (E) above, the IAI Global Note and in all other cases, the appropriate Unrestricted Global Note.

 

53


(2) Restricted Definitive Notes to Beneficial Interests in Unrestricted Global Notes. A Holder of a Restricted Definitive Note may exchange such Note for a beneficial interest in an Unrestricted Global Note or transfer such Restricted Definitive Note to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note only if the Registrar receives the following:

(A) if the Holder of such Definitive Notes proposes to exchange such Notes for a beneficial interest in the Unrestricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(c) thereof; or

(B) if the Holder of such Definitive Notes proposes to transfer such Notes to a Person who shall take delivery thereof in the form of a beneficial interest in the Unrestricted Global Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

and, in each such case set forth in this clause (2), if the Registrar so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Company to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

Upon satisfaction of the conditions of any of the subparagraphs in this Section 2.06(d)(2), the Trustee will cancel the Definitive Notes and increase or cause to be increased the aggregate principal amount of the Unrestricted Global Note.

(3) Unrestricted Definitive Notes to Beneficial Interests in Unrestricted Global Notes. A Holder of an Unrestricted Definitive Note may exchange such Note for a beneficial interest in an Unrestricted Global Note or transfer such Definitive Notes to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note at any time. Upon receipt of a request for such an exchange or transfer, the Trustee will cancel the applicable Unrestricted Definitive Note and increase or cause to be increased the aggregate principal amount of one of the Unrestricted Global Notes.

If any such exchange or transfer from a Definitive Note to a beneficial interest is effected pursuant to subparagraphs (2) or (3) above at a time when an Unrestricted Global Note has not yet been issued, the Company will issue and, upon receipt of an Authentication Order in accordance with Section 2.02, the Trustee will authenticate one or more Unrestricted Global Notes in an aggregate principal amount equal to the principal amount of Definitive Notes so transferred.

(e) Transfer and Exchange of Definitive Notes for Definitive Notes. Upon request by a Holder of Definitive Notes and such Holder’s compliance with the provisions of this Section 2.06(e), the Registrar will register the transfer or exchange of Definitive Notes. Prior to such registration of transfer or exchange, the requesting Holder must present or surrender to the Registrar the Definitive Notes duly endorsed or accompanied by a written instruction of transfer in form satisfactory to the Registrar duly executed by such Holder or by its attorney, duly authorized in writing. In addition, the requesting Holder must provide any additional certifications, documents and information, as applicable, required pursuant to the following provisions of this Section 2.06(e).

 

54


(1) Restricted Definitive Notes to Restricted Definitive Notes. Any Restricted Definitive Note may be transferred to and registered in the name of Persons who take delivery thereof in the form of a Restricted Definitive Note if the Registrar receives the following:

(A) if the transfer will be made pursuant to Rule 144A, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (1) thereof;

(B) if the transfer will be made pursuant to Rule 903 or Rule 904, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (2) thereof; and

(C) if the transfer will be made pursuant to any other exemption from the registration requirements of the Securities Act, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable.

(2) Restricted Definitive Notes to Unrestricted Definitive Notes. Any Restricted Definitive Note may be exchanged by the Holder thereof for an Unrestricted Definitive Note or transferred to a Person or Persons who take delivery thereof in the form of an Unrestricted Definitive Note if the Registrar receives the following:

(A) if the Holder of such Restricted Definitive Notes proposes to exchange such Notes for an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(d) thereof; or

(B) if the Holder of such Restricted Definitive Notes proposes to transfer such Notes to a Person who shall take delivery thereof in the form of an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

and, in each such case set forth in this clause (2), if the Registrar so requests, an Opinion of Counsel in form reasonably acceptable to the Registrar to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

(3) Unrestricted Definitive Notes to Unrestricted Definitive Notes. A Holder of Unrestricted Definitive Notes may transfer such Notes to a Person who takes delivery thereof in the form of an Unrestricted Definitive Note. Upon receipt of a request to register such a transfer, the Registrar shall register the Unrestricted Definitive Notes pursuant to the instructions from the Holder thereof.

 

55


(f) [Reserved].

(g) Legends. The following legends will appear on the face of all Global Notes and Definitive Notes issued under this Indenture unless specifically stated otherwise in the applicable provisions of this Indenture or any Supplemental Indenture governing Additional Notes.

(1) Private Placement Legend.

(A) Except as permitted by subparagraph (B) below, each Global Note and each Definitive Note (and all Notes issued in exchange therefor or substitution thereof) shall bear the legend in substantially the following form:

“THIS NOTE HAS NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), AND MAY NOT BE OFFERED, SOLD, PLEDGED OR OTHERWISE TRANSFERRED EXCEPT IN ACCORDANCE WITH THE FOLLOWING SENTENCE. BY ITS ACQUISITION HEREOF OR OF A BENEFICIAL INTEREST HEREIN, THE ACQUIRER AGREES FOR THE BENEFIT OF VENTURE GLOBAL CALCASIEU PASS, LLC THAT IT WILL NOT OFFER, SELL, PLEDGE OR OTHERWISE TRANSFER THIS NOTE OR ANY BENEFICIAL INTEREST HEREIN, EXCEPT IN ACCORDANCE WITH THE SECURITIES ACT AND ANY APPLICABLE SECURITIES LAWS OF ANY STATE OF THE UNITED STATES AND ONLY (A) TO VENTURE GLOBAL CALCASIEU PASS, LLC, (B) PURSUANT TO A REGISTRATION STATEMENT WHICH HAS BECOME EFFECTIVE UNDER THE SECURITIES ACT, (C) TO A QUALIFIED INSTITUTIONAL BUYER IN COMPLIANCE WITH RULE 144A UNDER THE SECURITIES ACT, (D) IN AN OFFSHORE TRANSACTION IN COMPLIANCE WITH RULE 904 OF REGULATION S UNDER THE SECURITIES ACT, (E) TO AN INSTITUTIONAL “ ACCREDITED INVESTOR” WITHIN THE MEANING OF RULE 501(a)(1), (2), (3) OR (7) UNDER THE SECURITIES ACT THAT IS NOT A QUALIFIED INSTITUTIONAL BUYER AND THAT IS PURCHASING FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF ANOTHER INSTITUTIONAL ACCREDITED INVESTOR, IN EACH CASE IN A MINIMUM PRINCIPAL AMOUNT OF THE SECURITIES OF $250,000, FOR INVESTMENT PURPOSES AND NOT WITH A VIEW TO OR FOR OFFER OR SALE IN CONNECTION WITH ANY DISTRIBUTION IN VIOLATION OF THE SECURITIES ACT OR (F) PURSUANT TO AN EXEMPTION FROM REGISTRATION PROVIDED BY RULE 144 UNDER THE SECURITIES ACT OR ANY OTHER AVAILABLE EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT. PRIOR TO THE REGISTRATION OF ANY TRANSFER IN ACCORDANCE WITH CLAUSES (C), (D) OR (E) ABOVE, A DULY COMPLETED AND SIGNED CERTIFICATE (THE FORM OF WHICH MAY BE OBTAINED FROM THE TRUSTEE) MUST BE DELIVERED TO THE TRUSTEE. PRIOR TO THE REGISTRATION OF ANY TRANSFER IN ACCORDANCE WITH (F) ABOVE, VENTURE GLOBAL CALCASIEU PASS, LLC RESERVES THE RIGHT TO REQUIRE THE

 

56


DELIVERY OF SUCH LEGAL OPINIONS, CERTIFICATIONS OR OTHER EVIDENCE AS MAY REASONABLY BE REQUIRED IN ORDER TO DETERMINE THAT THE PROPOSED TRANSFER IS BEING MADE IN COMPLIANCE WITH THE SECURITIES ACT AND APPLICABLE STATE SECURITIES LAWS. NO REPRESENTATION IS MADE AS TO THE AVAILABILITY OF ANY RULE 144 EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT.”

(B) Notwithstanding the foregoing, any Global Note or Definitive Note issued pursuant to subparagraphs (b)(4), (c)(3), (c)(4), (d)(2), (d)(3), (e)(2) or (e)(3) of this Section 2.06 (and all Notes issued in exchange therefor or substitution thereof) will not bear the Private Placement Legend.

(2) Global Note Legend. Each Global Note will bear a legend in substantially the following form:

“THIS GLOBAL NOTE IS HELD BY THE DEPOSITARY (AS DEFINED IN THE INDENTURE GOVERNING THIS NOTE) OR ITS NOMINEE IN CUSTODY FOR THE BENEFIT OF THE BENEFICIAL OWNERS HEREOF, AND IS NOT TRANSFERABLE TO ANY PERSON UNDER ANY CIRCUMSTANCES EXCEPT THAT (1) THE TRUSTEE MAY MAKE SUCH NOTATIONS HEREON AS MAY BE REQUIRED PURSUANT TO SECTION 2.06 OF THE INDENTURE, (2) THIS GLOBAL NOTE MAY BE EXCHANGED IN WHOLE BUT NOT IN PART PURSUANT TO SECTION 2.06(a) OF THE INDENTURE, (3) THIS GLOBAL NOTE MAY BE DELIVERED TO THE TRUSTEE FOR CANCELLATION PURSUANT TO SECTION 2.11 OF THE INDENTURE AND (4) THIS GLOBAL NOTE MAY BE TRANSFERRED TO A SUCCESSOR DEPOSITARY WITH THE PRIOR WRITTEN CONSENT OF THE COMPANY.

UNLESS AND UNTIL IT IS EXCHANGED IN WHOLE OR IN PART FOR NOTES IN DEFINITIVE FORM, THIS NOTE MAY NOT BE TRANSFERRED EXCEPT AS A WHOLE BY THE DEPOSITARY TO A NOMINEE OF THE DEPOSITARY OR BY A NOMINEE OF THE DEPOSITARY TO THE DEPOSITARY OR ANOTHER NOMINEE OF THE DEPOSITARY OR BY THE DEPOSITARY OR ANY SUCH NOMINEE TO A SUCCESSOR DEPOSITARY OR A NOMINEE OF SUCH SUCCESSOR DEPOSITARY. UNLESS THIS CERTIFICATE IS PRESENTED BY AN AUTHORIZED REPRESENTATIVE OF THE DEPOSITORY TRUST COMPANY (55 WATER STREET, NEW YORK, NEW YORK) (“DTC”), TO THE COMPANY OR ITS AGENT FOR REGISTRATION OF TRANSFER, EXCHANGE OR PAYMENT, AND ANY CERTIFICATE ISSUED IS REGISTERED IN THE NAME OF CEDE & CO. OR SUCH OTHER NAME AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC (AND ANY PAYMENT IS MADE TO CEDE & CO. OR SUCH OTHER ENTITY AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC), ANY TRANSFER, PLEDGE OR OTHER USE HEREOF FOR VALUE OR OTHERWISE BY OR TO ANY PERSON IS WRONGFUL INASMUCH AS THE REGISTERED OWNER HEREOF, CEDE & CO., HAS AN INTEREST HEREIN.”

 

57


(3) Regulation S Temporary Global Note Legend. The Regulation S Temporary Global Note will bear a legend in substantially the following form:

“THE RIGHTS ATTACHING TO THIS REGULATION S TEMPORARY GLOBAL NOTE, AND THE CONDITIONS AND PROCEDURES GOVERNING ITS EXCHANGE FOR CERTIFICATED NOTES, ARE AS SPECIFIED IN THE INDENTURE (AS DEFINED HEREIN). NEITHER THE HOLDER NOR THE BENEFICIAL OWNERS OF THIS REGULATION S TEMPORARY GLOBAL NOTE SHALL BE ENTITLED TO RECEIVE PAYMENT OF INTEREST HEREON.”

(h) Cancellation and/or Adjustment of Global Notes. At such time as all beneficial interests in a particular Global Note have been exchanged for Definitive Notes or a particular Global Note has been redeemed, repurchased or canceled in whole and not in part, each such Global Note will be returned to or retained and canceled by the Trustee in accordance with Section 2.11. At any time prior to such cancellation, if any beneficial interest in a Global Note is exchanged for or transferred to a Person who will take delivery thereof in the form of a beneficial interest in another Global Note or for Definitive Notes, the principal amount of Notes represented by such Global Note will be reduced accordingly and an endorsement will be made on such Global Note by the Trustee or by the Depositary at the direction of the Trustee to reflect such reduction; and if the beneficial interest is being exchanged for or transferred to a Person who will take delivery thereof in the form of a beneficial interest in another Global Note, such other Global Note will be increased accordingly and an endorsement will be made on such Global Note by the Trustee or by the Depositary at the direction of the Trustee to reflect such increase.

(i) General Provisions Relating to Transfers and Exchanges.

(1) To permit registrations of transfers and exchanges, the Company will execute and the Trustee will authenticate Global Notes and Definitive Notes upon receipt of an Authentication Order in accordance with Section 2.02 or at the Registrar’s request.

(2) No service charge will be made to a Holder of a beneficial interest in a Global Note or to a Holder of a Definitive Note for any registration of transfer or exchange, but the Company may require payment of a sum sufficient to cover any transfer tax or similar governmental charge payable in connection therewith (other than any such transfer taxes or similar governmental charge payable upon exchange or transfer pursuant to Section 2.10, Section 3.06, Section 3.09, Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 and Section 9.06).

(3) The Registrar will not be required to register the transfer of or exchange of any Note selected for redemption in whole or in part, except the unredeemed portion of any Note being redeemed in part.

 

58


(4) All Global Notes and Definitive Notes issued upon any registration of transfer or exchange of Global Notes or Definitive Notes will be the valid obligations of the Company, evidencing the same debt, and entitled to the same benefits under this Indenture, as the Global Notes or Definitive Notes surrendered upon such registration of transfer or exchange.

(5) Neither the Registrar nor the Company will be required:

(A) to issue, to register the transfer of or to exchange any Notes during a period beginning at the opening of business 15 days before the day of any selection of Notes for redemption under Section 3.02 and ending at the close of business on the day of selection;

(B) to register the transfer of or to exchange any Note selected for redemption in whole or in part, except the unredeemed portion of any Note being redeemed in part; or

(C) to register the transfer of or to exchange a Note between a record date and the next succeeding Interest Payment Date.

(6) Prior to due presentment for the registration of a transfer of any Note, the Trustee, any Agent and the Company may deem and treat the Person in whose name any Note is registered as the absolute owner of such Note for the purpose of receiving payment of principal of and interest on such Notes and for all other purposes, and none of the Trustee, any Agent or the Company shall be affected by notice to the contrary.

(7) The Trustee will authenticate Global Notes and Definitive Notes in accordance with the provisions of Section 2.02.

(8) All certifications, certificates and Opinions of Counsel required to be submitted to the Registrar pursuant to this Section 2.06 to effect a registration of transfer or exchange may be submitted by facsimile.

(9) None of the Trustee or any Agent shall have any responsibility or obligation to any beneficial owner in a Global Note, an agent member of the Depositary or other Person with respect to the accuracy of the records of the Depositary or its nominee or of any agent member of the Depositary, with respect to any ownership interest in the Notes or with respect to the delivery to any agent member of the Depositary, beneficial owner or other Person (other than the Depositary) of any notice (including any notice of redemption) or the payment of any amount, under or with respect to such Notes. All notices and communications to be given to the Holders and all payments to be made to Holders under the Notes and this Indenture shall be given or made only to or upon the order of the registered holders (which shall be the Depositary or its nominee in the case of the Global Note). The rights of beneficial owners in the Global Note shall be exercised only through the Depositary subject to the applicable procedures. The Trustee and each Agent shall be entitled to rely and shall be fully protected in relying upon information furnished by the Depositary with respect to its members, participants and any beneficial owners. The Trustee and each Agent shall be entitled to deal with the Depositary, and any nominee thereof, that is the registered holder of any Global Note for all purposes of this Indenture relating to such Global Note (including the payment of principal, premium, if any, and

 

59


interest, and the giving of instructions or directions by or to the owner or holder of a beneficial ownership interest in such Global Note) as the sole holder of such Global Note and shall have no obligations to the beneficial owners thereof. None of the Trustee or any Agent shall have any responsibility or liability for any acts or omissions of the Depositary with respect to such Global Note, for the records of any such depositary, including records in respect of beneficial ownership interests in respect of any such Global Note, for any transactions between the Depositary and any agent member of the Depositary or between or among the Depositary, any such agent member of the Depositary and/or any holder or owner of a beneficial interest in such Global Note, or for any transfers of beneficial interests in any such Global Note.

(10) Notwithstanding the foregoing, with respect to any Global Note, nothing herein shall prevent the Company, the Trustee, any Agent, or any agent of the Company or the Trustee from giving effect to any written certification, proxy or other authorization furnished by any Depositary (or its nominee), as a Holder, with respect to such Global Note or shall impair, as between such Depositary and owners of beneficial interests in such Global Note, the operation of customary practices governing the exercise of the rights of such Depositary (or its nominee) as Holder of such Global Note.

(11) None of the Trustee or any Agent shall have any obligation or duty to monitor, determine or inquire as to compliance with any restrictions on transfer imposed under this Indenture or under applicable law with respect to any transfer of any interest in any security (including any transfers between or among Depositary participants, members or beneficial owners in any Global Note) other than to require delivery of such certificates and other documentation or evidence as are expressly required by, and to do so if and when expressly required by, the terms of this Indenture, and to examine the same to determine substantial compliance as to form with the express requirements hereof.

Section 2.07 Replacement Notes.

If any mutilated Note is surrendered to the Trustee or the Company and the Trustee receives evidence to its satisfaction of the destruction, loss or theft of any Note, the Company will issue and the Trustee, upon receipt of an Authentication Order, will authenticate a replacement Note if the Trustee’s requirements are met. If required by the Trustee or the Company, an indemnity bond must be supplied by the Holder that is sufficient in the judgment of the Trustee and the Company to protect the Company, the Trustee, any Agent and any authenticating agent from any loss that any of them may suffer if a Note is replaced. The Company may charge for its expenses in replacing a Note.

Every replacement Note is an additional obligation of the Company and will be entitled to all of the benefits of this Indenture equally and proportionately with all other Notes duly issued hereunder.

 

60


Section 2.08 Outstanding Notes.

The Notes outstanding at any time are all the Notes authenticated by the Trustee except for those canceled by it, those delivered to it for cancellation, those reductions in the interest in a Global Note effected by the Trustee in accordance with the provisions hereof, and those described in this Section 2.08 as not outstanding. Except as set forth in Section 2.09, a Note does not cease to be outstanding because the Company or an Affiliate of the Company holds the Note; however, Notes held by the Company or an Affiliate of the Company shall not be deemed to be outstanding for purposes of Section 3.07.

If a Note is replaced pursuant to Section 2.07, it ceases to be outstanding unless the Trustee receives proof satisfactory to it that the replacement Note is held by a “protected purchaser” under the uniform commercial code.

If the principal amount of any Note is considered paid under Section 4.01, it ceases to be outstanding and interest on it ceases to accrue.

If the Paying Agent (other than the Company, a Subsidiary or an Affiliate of any thereof) holds, on a redemption date or maturity date, money sufficient to pay Notes payable on that date, then on and after that date such Notes will be deemed to be no longer outstanding and will cease to accrue interest.

Section 2.09 Treasury Notes.

In determining whether the Holders of the required principal amount of Notes have concurred in any direction, waiver or consent, Notes owned by the Company or any Guarantor, or by any Person directly or indirectly controlling or controlled by or under direct or indirect common control with the Company or any Guarantor, will be considered as though not outstanding, except that for the purposes of determining whether the Trustee will be protected in relying on any such direction, waiver or consent, only Notes that the Trustee knows are so owned will be so disregarded.

Section 2.10 Temporary Notes.

Until certificates representing Notes are ready for delivery, the Company may prepare and the Trustee, upon receipt of an Authentication Order, will authenticate temporary Notes. Temporary Notes will be substantially in the form of certificated Notes but may have variations that the Company considers appropriate for temporary Notes and as may be reasonably acceptable to the Trustee. Without unreasonable delay, the Company will prepare and the Trustee will authenticate definitive Notes in exchange for temporary Notes.

Holders of temporary Notes will be entitled to all of the benefits of this Indenture.

Section 2.11 Cancellation.

The Company at any time may deliver Notes to the Trustee for cancellation. The Registrar and Paying Agent will forward to the Trustee any Notes surrendered to them for registration of transfer, exchange or payment. The Trustee and no one else will cancel all Notes surrendered for registration of transfer, exchange, payment, replacement or cancellation and will destroy canceled Notes (subject to the record retention requirement of the Exchange Act). Certification of the destruction of all canceled Notes will be delivered to the Company. The Company may not issue new Notes to replace Notes that it has paid or that have been delivered to the Trustee for cancellation.

 

61


Section 2.12 Defaulted Interest.

If the Company defaults in a payment of interest on the Notes, it will pay the defaulted interest in any lawful manner plus, to the extent lawful, interest payable on the defaulted interest, to the Persons who are Holders on a subsequent special record date, in each case at the rate provided in the Notes and in Section 4.01. The Company will notify the Trustee in writing of the amount of defaulted interest proposed to be paid on each Note and the date of the proposed payment. The Company will fix or cause to be fixed each such special record date and payment date; provided that no such special record date may be less than 10 days prior to the related payment date for such defaulted interest. At least 15 days before the special record date, the Company (or, upon the written request of the Company, the Trustee in the name and at the expense of the Company) will deliver Holders a notice that states the special record date, the related payment date and the amount of such interest to be paid.

ARTICLE 3

REDEMPTION AND OFFERS TO PURCHASE NOTES

Section 3.01 Notices to Trustee.

If the Company elects to redeem Notes pursuant to the optional redemption provisions of Section 3.07, it must furnish to the Trustee, at least 10 days but not more than 60 days before a redemption date, an Officer’s Certificate setting forth:

 

  (1)

the Section of this Indenture pursuant to which the redemption shall occur;

 

  (2)

the redemption date;

 

  (3)

the series, or more than one series, if applicable, of Notes to be redeemed;

 

  (4)

the principal amount of Notes to be redeemed;

 

  (5)

the redemption price; and

 

  (6)

the CUSIP number of the Notes to be redeemed.

Section 3.02 Selection of Notes to Be Redeemed.

If less than all of the Notes are to be redeemed at any time, or less than all of the Notes of a particular series are to be redeemed, the Trustee will select Notes for redemption by lot, on a pro rata basis (provided that, in the case of Global Notes, the Depositary may select Global Notes for redemption pursuant to its Applicable Procedures) and, if applicable, with such adjustments that may be deemed appropriate by the Trustee so that only Notes in denominations of $2,000 or whole multiples of $1,000 in excess thereof will be purchased unless otherwise required by law, Depositary requirements, or applicable stock exchange requirements; provided that if only Notes of a particular series are to be redeemed, such selection by the Trustee shall be limited to Notes of such series.

 

62


No Notes of $2,000 or less can be redeemed in part. In the event of partial redemption, the particular Notes to be redeemed will be selected, unless otherwise provided herein, not less than 30 nor more than 60 days prior to the redemption or purchase date by the Trustee from the outstanding Notes not previously called for redemption.

The Trustee will promptly notify the Company in writing of the Notes selected for redemption and, in the case of any Note selected for partial redemption, the principal amount thereof to be redeemed. Notes and portions of Notes selected will be in amounts of $2,000 or whole multiples of $1,000 in excess thereof; except that if all of the Notes of a Holder are to be redeemed, the entire outstanding amount of Notes held by such Holder, even if not in the amount of $2,000 or a whole multiple of $1,000 thereof, shall be redeemed. Except as provided in the preceding sentence, provisions of this Indenture that apply to Notes called for redemption also apply to portions of Notes called for redemption.

Section 3.03 Notice of Redemption.

At least 10 days but not more than 60 days before a redemption date, the Company will deliver a notice of redemption to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes of a series or a satisfaction and discharge of this Indenture pursuant to Article 8 or 12.

The notice will identify the Notes to be redeemed and will state:

(1) the redemption date;

(2) the redemption price;

(3) if any Note is being redeemed in part, the portion of the principal amount of such Note to be redeemed and that, after the redemption date upon surrender of such Note, a new Note or Notes in principal amount equal to the unredeemed portion will be issued in the name of the Holder upon cancellation of the original Note;

(4) the name and address of the Paying Agent;

(5) that Notes called for redemption must be surrendered to the Paying Agent to collect the redemption price;

(6) that, unless the Company defaults in making such redemption payment, interest on Notes called for redemption ceases to accrue on and after the redemption date;

(7) the paragraph of the Notes and/or Section of this Indenture pursuant to which the Notes called for redemption are being redeemed; and

 

63


(8) that no representation is made as to the correctness or accuracy of the CUSIP number, if any, listed in such notice or printed on the Notes.

At the Company’s request, the Trustee will give the notice of redemption in the Company’s name and at its expense; provided, however, that the Company has delivered to the Trustee, at least 45 days prior to the redemption date (unless a shorter period is acceptable to the Trustee), an Officer’s Certificate requesting that the Trustee give such notice and setting forth the information to be stated in such notice as provided in the preceding paragraph.

Any redemption or notice of any redemption may, at the Company’s discretion, be subject to one or more conditions precedent, including, but not limited to, completion of any debt or equity financing, acquisition or other corporate transaction or event, and, at Company’s discretion, the redemption date may be delayed until such time as any or all of such conditions have been satisfied. In addition, the Company may provide in any notice of redemption that payment of the redemption price and the performance of the Company’s obligations with respect to such redemption may be performed by another person; provided, however, that the Company will remain obligated to pay the redemption price and perform its obligations with respect to such redemption in the event such other person fails to do so and all conditions to such redemption, if any, are satisfied.

Section 3.04 Effect of Notice of Redemption.

Once notice of redemption is delivered in accordance with Section 3.03, Notes called for redemption become irrevocably due and payable on the redemption date at the redemption price.

Section 3.05 Deposit of Redemption or Purchase Price.

At least one Business Day prior to the redemption date, the Company will deposit or will cause to be deposited with the Trustee or with the Paying Agent money sufficient to pay the redemption price of and accrued interest, if any, on all Notes to be redeemed on that date. The Trustee or the Paying Agent will promptly return to the Company any money deposited with the Trustee or the Paying Agent by the Company in excess of the amounts necessary to pay the redemption price of, and accrued interest, if any, on, all Notes to be redeemed.

If the Company complies with the provisions of the preceding paragraph, on and after the redemption date, interest will cease to accrue on the Notes or the portions of Notes called for redemption. If a Note is redeemed on or after an interest record date but on or prior to the related Interest Payment Date, then any accrued and unpaid interest shall be paid to the Person in whose name such Note was registered at the close of business on such record date. If any Note called for redemption is not so paid upon surrender for redemption because of the failure of the Company to comply with the preceding paragraph, interest shall be paid on the unpaid principal, from the redemption or purchase date until such principal is paid, and to the extent lawful on any interest not paid on such unpaid principal, in each case at the rate provided in the Notes and in Section 4.01.

 

64


Section 3.06 Notes Redeemed in Part.

Upon surrender of a Note that is redeemed in part, the Company will issue and, upon receipt of an Authentication Order, the Trustee will authenticate for the Holder at the expense of the Company a new Note equal in principal amount to the unredeemed portion of the Note surrendered.

Section 3.07 Optional Redemption.

At any time or from time to time prior to February 15, 2029 (the “2029 Call Date”), the Company may, at its option, redeem all or a part of the 2029 Notes at a redemption price equal to the 2029 Make-Whole Price plus accrued and unpaid interest on such 2029 Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

2029 Make-Whole Price” with respect to any 2029 Notes to be redeemed, means an amount equal to the greater of:

(1) 100% of the principal amount of such 2029 Notes, without any premium, penalty or charge; and

(2) an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2029 Call Date (assuming the principal amount is scheduled to be paid on the 2029 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate (as defined below) plus 50 basis points.

At any time on or after the 2029 Call Date, the Company may, at its option, redeem all or a part of the 2029 Notes, at a redemption price equal to 100% of the principal amount of the 2029 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

At any time or from time to time prior to February 15, 2031 (the “2031 Call Date”), the Company may, at its option, redeem all or a part of the 2031 Notes at a redemption price equal to the 2031 Make-Whole Price plus accrued and unpaid interest on such 2031 Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

2031 Make-Whole Price” with respect to any 2031 Notes to be redeemed, means an amount equal to the greater of:

(1) 100% of the principal amount of such 2031 Notes, without any premium, penalty or charge; and

 

65


(2) an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2031 Call Date (assuming the principal amount is scheduled to be paid on the 2031 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate (as defined below) plus 50 basis points.

At any time on or after the 2031 Call Date, the Company may, at its option, redeem all or a part of the 2031 Notes, at a redemption price equal to 100% of the principal amount of the 2031 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

Treasury Rate” means the yield to maturity at the time of computation of United States Treasury securities with a constant maturity (as compiled and published in the most recent Federal Reserve Statistical Release H.15 (519) which has become publicly available at least two Business Days (but not more than five Business Days) prior to the relevant redemption date (or, if such Statistical Release is not so published or available, any publicly available source of similar market data selected by the Company in good faith)) most nearly equal to the period from the redemption date to the 2029 Call Date or the 2031 Call Date, as applicable, on which the principal of the Notes of the applicable series being redeemed will be paid in full; provided, however, that if the period from the redemption date to such 2029 Call Date or 2031 Call Date, as applicable, is not equal to the constant maturity of a United States Treasury security for which a weekly average yield is given, the Treasury Rate shall be obtained by linear interpolation (calculated to the nearest one- twelfth of a year) from the weekly average yields of United States Treasury securities for which such yields are given, except that if the period from the redemption date to such 2029 Call Date or 2031 Call Date, as applicable, is less than one year, the weekly average yield on actually traded United States Treasury securities adjusted to a constant maturity of one year shall be used.

The notice of redemption with respect to the foregoing redemption need not set forth the 2029 Make-Whole Price or 2031 Make-Whole Price, as applicable, but only the manner of calculation thereof. The Company will determine the redemption price (including any 2029 Make- Whole Price or 2031 Make-Whole Price, as applicable) and will notify the Trustee of the redemption price (including any 2029 Make-Whole Price or 2031 Make-Whole Price, as applicable) with respect to any redemption promptly, and the Trustee shall not be responsible for such calculation or determination.

Section 3.08 Open Market Purchases; No Mandatory Redemption or Sinking Fund.

The Company, TCP and their respective Restricted Subsidiaries may at any time and from time to time purchase Notes in the open market or otherwise. The Company is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

 

66


Section 3.09 Offer to Purchase by Application of Excess Proceeds, Excess Loss Proceeds, PLD Excess Proceeds and LNG SPA Mandatory Offer Amount.

In the event that, pursuant to Section 4.12, Section 4.19, Section 4.20, or Section 4.21, the Company is required to commence an offer to all Holders to purchase Notes (an “Asset Sale Offer,” an “Excess Loss Proceeds Offer,” a “PLD Excess Proceeds Offer” or a “LNG SPA Mandatory Offer” respectively), it will follow the procedures specified below.

The Asset Sale Offer, the Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable, shall be made to all Holders of Notes of each series and all holders of all other Senior Debt (or will prepay such Senior Debt) then outstanding containing provisions similar to those set forth in this Indenture with respect to offers to purchase or redeem or requirements to prepay (i) with the proceeds of sales of assets, (ii) with the proceeds of an event of loss, (iii) with the proceeds of PLD Excess Proceeds, or (iv) as a result of LNG SPA prepayment events, to purchase, redeem or repay, as applicable, the maximum principal amount of Notes of each series and such other Senior Debt that may be purchased, redeemed or repaid out of such proceeds. The Asset Sale Offer, the Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable, with respect to all Holders will remain open for a period of at least 20 Business Days following its commencement and not more than 30 Business Days, except to the extent that a longer period is required by applicable law (the “Offer Period”). No later than three Business Days after the termination of the Offer Period (the “Purchase Date”), the Company will apply all Excess Proceeds, Excess Loss Proceeds, PLD Excess Proceeds or LNG SPA Mandatory Offer Amount, as applicable (the “Offer Amount”), to the purchase of Notes of each series and such other Senior Debt (on a pro rata basis, if applicable, pursuant to the pro rata payment provisions in the CSAA) or, if less than the Offer Amount has been tendered, all Notes and other Indebtedness tendered in response to the Asset Sale Offer, the Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable. Payment for any Notes so purchased will be made in the same manner as interest payments are made hereunder.

If the Purchase Date is on or after an interest record date and on or before the related Interest Payment Date, any accrued and unpaid interest, if any, will be paid to the Person in whose name a Note is registered at the close of business on such record date, and no additional interest will be payable to Holders who tender Notes pursuant to the Asset Sale Offer, the Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable.

Upon the commencement of an Asset Sale Offer, Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable, the Company will deliver a notice to each of the Holders, with a copy to the Trustee. The notice will contain all instructions and materials necessary to enable such Holders to tender Notes pursuant to the Asset Sale Offer, the Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable. The notice, which will govern the terms of the Asset Sale Offer, Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable, will state:

(1) that the Asset Sale Offer, Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable, is being made pursuant to this Section 3.09 and Section 4.12, Section 4.19, Section 4.20, or Section 4.21, as applicable, and the length of time the Asset Sale Offer, Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable, will remain open;

 

67


(2) the Offer Amount, the purchase price and the Purchase Date;

(3) that any Note not tendered or accepted for payment will continue to accrete or accrue interest;

(4) that, unless the Company defaults in making such payment, any Note accepted for payment pursuant to the Asset Sale Offer, Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable, will cease to accrete or accrue interest after the Purchase Date;

(5) that Holders electing to have a Note purchased pursuant to an Asset Sale Offer, Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable, may elect to have Notes purchased in integral multiples of $2,000 and integral multiples of $1,000 in excess thereof only;

(6) that Holders electing to have Notes purchased pursuant to an Asset Sale Offer, Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable, will be required to surrender the Note, with the form entitled “Option of Holder to Elect Purchase” attached to the Notes completed, or transfer by book-entry transfer, to the Company, a Depositary, if appointed by the Company, or a Paying Agent at the address specified in the notice at least three days before the Purchase Date;

(7) that Holders will be entitled to withdraw their election if the Company, the Depositary or the Paying Agent, as the case may be, receives, not later than the expiration of the Offer Period, a telegram, telex, facsimile transmission or letter setting forth the name of the Holder, the principal amount of the Note the Holder delivered for purchase and a statement that such Holder is withdrawing his election to have such Note purchased;

(8) that, if the aggregate principal amount of Notes and other Senior Debt tendered by Holders thereof or required to be prepaid, exceeds the Offer Amount, the Notes, and such other Senior Debt, shall be purchased on a pro rata basis as determined pursuant to the CSAA and, in the case of Global Notes, the Depositary shall select the Notes of each series or portions thereof to be purchased pursuant to its policies and procedures or, in the case of certificated Notes, the Trustee will select the Notes or portions thereof to be purchased by lot, on a pro rata basis; provided that, in the case of Global Notes, the Depositary may select Global Notes for redemption pursuant to its Applicable Procedures (and, if applicable, with respect to the Notes, with such adjustments as may be deemed appropriate by the Trustee so that only Notes in denominations of $2,000 and integral multiples of $1,000 in excess thereof, will be purchased); and

 

68


(9) that Holders whose Notes were purchased only in part will be issued new Notes equal in principal amount to the unpurchased portion of the Notes surrendered (or transferred by book-entry transfer).

On or before the Purchase Date, the Company will, to the extent lawful, accept for payment, on a pro rata basis to the extent necessary, the Offer Amount of Notes or portions thereof tendered pursuant to the Asset Sale Offer, Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable, or if less than the Offer Amount has been tendered, all Notes tendered, and will deliver or cause to be delivered to the Trustee the Notes properly accepted together with an Officer’s Certificate stating that such Notes or portions thereof were accepted for payment by the Company in accordance with the terms of this Section 3.09. The Company, the Depositary or the Paying Agent, as the case may be, will promptly (but in any case not later than five days after the Purchase Date) mail or deliver to each tendering Holder an amount equal to the purchase price of the Notes tendered by such Holder and accepted by the Company for purchase, and the Company will promptly issue a new Note, and the Trustee, upon written request from the Company, will authenticate and mail or deliver (or cause to be transferred by book entry) such new Note to such Holder, in a principal amount equal to any unpurchased portion of the Note surrendered. Any Note not so accepted shall be promptly mailed or delivered by the Company to the Holder thereof. The Company will publicly announce the results of the Asset Sale Offer, the Excess Loss Proceeds Offer, the PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer, as applicable, on the Purchase Date.

ARTICLE 4

COVENANTS

Section 4.01 Payment of Notes.

The Company will pay or cause to be paid the principal of, premium, if any, and interest, if any, on, the Notes of each series on the dates and in the manner provided in the Notes of each series. Principal, premium, if any, and interest, if any, will be considered paid on the date due if the Paying Agent, if other than the Company or a Subsidiary thereof, holds as of 12:00 p.m. Eastern Time on the due date money deposited by the Company in immediately available funds and designated for and sufficient to pay all principal, premium, if any, and interest, if any, then due.

The Company will (a) pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue principal at the rate equal to 0.50% per annum in excess of the then applicable interest rate on the Notes of each series to the extent lawful and (b) pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue installments of interest (without regard to any applicable grace period) at the rate equal to 0.50% per annum in excess of the then applicable interest rate on the Notes of such series to the extent lawful.

 

69


Section 4.02 Maintenance of Office or Agency.

The Company will maintain in the Borough of Manhattan, the City of New York, an office or agency (which may be an office of the Trustee or an Affiliate of the Trustee, Registrar or co- registrar) where Notes may be surrendered for registration of transfer or for exchange and where notices and demands to or upon the Company in respect of the Notes and this Indenture may be served. The Company will give written notice to the Trustee of the location, and any change in the location, of such office or agency. If at any time the Company fails to maintain any such required office or agency or fails to furnish the Trustee with the address thereof, such presentations, surrenders, notices and demands may be made or served at the Corporate Trust Office of the Trustee.

The Company may also from time to time designate one or more other offices or agencies where the Notes may be presented or surrendered for any or all such purposes and may from time to time rescind such designations; provided, however, that no such designation or rescission will in any manner relieve the Company of its obligation to maintain an office or agency in the Borough of Manhattan, the City of New York for such purposes. The Company will give written notice to the Trustee of any such designation or rescission and of any change in the location of any such other office or agency.

The Company hereby designates the Corporate Trust Office of the Trustee as one such office or agency of the Company in accordance with Section 2.03.

Section 4.03 Reporting Requirements.

(a) If the Company becomes subject to the reporting requirements of Section 13 or 15(d) of the Exchange Act, then the Company will file with the Trustee, within 15 days after the Company files them with the SEC, copies of its annual reports and of the information, documents and other reports (or copies of such portions of any of the foregoing as the SEC may by rules and regulations prescribe) that the Company is required to file with the SEC pursuant to Section 13 or 15(d) of the Exchange Act.

(b) The Company will, so long as any Notes are outstanding and are “restricted securities” within the meaning of Rule 144(a)(3) under the Securities Act, furnish to the Trustee and to the Holders and beneficial owners of the Notes, upon their request, the information required to be delivered pursuant to Rule 144A(d)(4) under the Securities Act (or any successor provision thereto) (“Rule 144A Information”), if at the time of such request the Company is not a reporting company under Section 13 or Section 15(d) of the Exchange Act or exempt from reporting pursuant to Rule 12g3-2(b) thereunder.

(c) So long as any of the Notes are outstanding, the Company will furnish or cause to be furnished to the Trustee (a) within 60 days following the end of the first three fiscal quarters of each fiscal year, consolidated unaudited statements of income and cash flows of each Obligor for such period and for the period from the beginning of the respective fiscal year to the end of such period and the related balance sheet as at the end of such period, setting forth in each case in comparative form the corresponding figures for the corresponding period in the preceding fiscal year and (b) within 120 days after the end of each fiscal year, its consolidated annual financial statements, audited by the Independent Accountants, in each case prepared in accordance with GAAP, subject, in the case of a quarterly financial statement, to the absence of notes and normal year-end audit adjustments.

 

70


(d) Notwithstanding the foregoing, any reports or other information required to be filed, delivered or furnished pursuant to this Section 4.03 shall be deemed filed, delivered or furnished if filed electronically with the SEC through the SEC’s Electronic Data Gathering, Analysis and Retrieval System (or any successor system).

(e) Delivery of the above reports and other documents to the Trustee is for informational purposes only and the Trustee’s receipt of such shall not constitute actual or constructive knowledge or notice of any information contained therein or determinable from information contained therein, including the Company’s compliance with any of its covenants hereunder (as to which the Trustee is entitled to rely exclusively on Officer’s Certificates).

Section 4.04 Compliance Certificate.

(a) The Company will deliver to the Trustee, accompanying the annual financial statements as described in Section 4.03 of this Indenture, a statement regarding compliance with this Indenture in an Officer’s Certificate also confirming that, to the signing officer’s knowledge, no Event of Default or Unmatured Event of Default has occurred and is Continuing which has not been waived, or, if the same has occurred, a description of any measures taken or proposed to be taken by the Company to address the same.

(b) So long as any of the Notes are outstanding, upon becoming aware of any Unmatured Event of Default or Event of Default, the Company is required to deliver to the Trustee an Officer’s Certificate specifying such Unmatured Event of Default or Event of Default and what action the Company is taking or proposes to take with respect thereto.

Section 4.05 Taxes.

Each of the Company, TCP and their respective Restricted Subsidiaries (or, for the purposes of this Section 4.05, if such entity is a disregarded entity for U.S. federal income tax purposes, its owner for U.S. federal income tax purposes) will pay or cause to be paid all material Taxes (if any) imposed on it or its property by any Governmental Authority, when due, giving effect to any applicable extensions, unless these are being contested in good faith and by appropriate proceedings and an appropriate reserve has been established in respect thereof in accordance with GAAP.

Section 4.06 Restricted Payments.

Restricted Payments by the Company, TCP or any Restricted Subsidiary may be made up to once monthly; provided that each of the following conditions has been satisfied:

(a) with respect to any Restricted Payment to be made on or prior to Facility Substantial Completion having occurred:

(1) no Event of Default or Unmatured Event of Default has occurred and is Continuing or would reasonably be expected to occur as a result of such Restricted Payment;

 

71


(2) LNG Production System Substantial Completion in respect of LPS1 has occurred;

(3) no LNG SPA Mandatory Prepayment or Indenture LNG SPA Prepayment Event, as the case may be, has occurred and is continuing in respect of which the LNG SPA Mandatory Offer required by the occurrence of such event in accordance with Section 4.21 has not been made and all tendered Notes purchased;

(4) the Company shall have delivered to the Trustee a certificate of an Authorized Officer of the Company certifying that it has access to sufficient committed or available funds necessary to achieve Facility Substantial Completion on or before the “facility substantial completion deadline” (as defined in the EPC Contract) and, upon Facility Substantial Completion will have sufficient funds to fund the Senior Facilities Debt Service Reserve Account and each Additional Debt Service Reserve Account to the then required level;

(5) the sum of (A) amounts on deposit in the Contingency Reserve Account and (B) the aggregate amount of restricted cash on the Company’s balance sheet available for the payment of contingency necessary to achieve Facility Substantial Completion equals or exceeds (x) prior to Substantial Completion in respect of LNG Production System 3, an amount equal to the Pre-LNG Production System Fixed Amount, (y) on or after Substantial Completion in respect of LNG Production System 3, $[***] and (z) on or after Facility Substantial Completion, the greater of (I) $[***] and (II) the sum of (1) then-current Reserve Amount, (2) the amount required to be funded in the Senior Facilities Debt Service Reserve Account (or, if the Senior Facilities Debt Service Reserve Account is not yet required to be funded, the amount that will be required to be funded therein on the first date on which it is required to be funded) and (3) the amount required to be funded into each other Additional Debt Service Reserve Account (if any) (or, if any such Additional Debt Service Reserve Account is not yet required to be funded, the amount that will be required to be funded therein on the first date on which such Additional Debt Service Reserve Account is required to be funded);

(6) unless, as of the date such Restricted Payment is to be made, the Notes are Investment Grade, the Independent Engineer shall have certified to the Trustee that it concurs with the Company’s certifications in clause (2) and (4) above;

(7) (A) either the Additional Debt Service Reserve Account opened for the Notes or the Contingency Reserve Account is funded (with cash or an Acceptable Debt Service Reserve LC) in an amount no less than the then-current Reserve Amount and (B) either the Contingency Reserve Account (as contemplated by clause (v) above) or the Senior Facilities Debt Service Reserve Account and each other Additional Debt Service Reserve Account (if any), as applicable, is funded (in each case, with cash or Acceptable Debt Service Reserve LCs) in the amount required by the applicable Finance Document; and

 

72


(8) the Trustee has received a certificate of an Authorized Officer of the Company confirming that each of the conditions set forth in clauses (a)(1) through (a)(7) above has been satisfied.

(b) with respect to any Restricted Payment to be made on or after the date on which Facility Substantial Completion occurs:

(1) no Event of Default or Unmatured Event of Default has occurred and is Continuing or would occur as a result of such Restricted Payment;

(2) the Historical DSCR and the Projected Fixed DSCR, each for the Calculation Period, are both at least 1.25:1;

(3) (A) the Additional Debt Service Reserve Account opened for the Notes is funded (with cash or an Acceptable Debt Service Reserve LC) in an amount no less than the then-current Reserve Amount and (B) the Senior Facilities Debt Service Reserve Account and each other Additional Debt Service Reserve Account (if any) is funded (in each case, with cash or Acceptable Debt Service Reserve LCs) in the amount required by the applicable Finance Document;

(4) no LNG SPA Mandatory Prepayment or Indenture LNG SPA Prepayment Event, as the case may be, has occurred and is continuing in respect of which the LNG SPA Mandatory Offer required by the occurrence of such event in accordance with Section 4.21 has not been made and all tendered Notes purchased;

(5) Facility Substantial Completion has occurred, as evidenced by the certificate of the Independent Engineer delivered pursuant to Section 4.36 (it being understood that such certificate shall only be required with respect to the first Restricted Payment to be made on or after the date on which Facility Substantial Completion occurs); and

(6) the Trustee has received a certificate of an Authorized Officer of the Company confirming that each of the conditions set forth in clauses (b)(1) through (b)(7) above has been satisfied and setting forth the calculation of Historical DSCR and Projected Fixed DSCR in clause (b)(2) above.

In addition to the Restricted Payments contemplated by clauses (a) and (b), the Obligors shall be permitted to make Restricted Payments (A) to reimburse equity contributed to the Obligors to complete or repair the Project Facilities in respect of which performance liquidated damages were subsequently received, to commence repairs or to replace property subject to loss prior to receipt of insurance proceeds or condemnation proceeds or to pay Project Costs at times when loans were not available under the Credit Facility Agreement, (B) as permitted by the Common Terms Agreement and the CSAA on the project completion date under the Common Terms Agreement with revenues earned prior to such project completion date, (C) so long as no Event of Default or Unmatured Event of Default has occurred and is continuing, certain tax distributions as permitted by the Common Terms Agreement and (D) so long as no Event of Default or Unmatured Event of Default has occurred and is continuing, with the net proceeds of Additional Senior Debt incurred on or after the date on which Facility Substantial Completion occurs.

 

73


Section 4.07 Dividend and Other Payment Restrictions Affecting Subsidiaries.

(a) Each of the Company and TCP will not, and will not permit any of its respective Restricted Subsidiaries to, directly or indirectly, create or permit to exist or become effective any consensual encumbrance or restriction on the ability of any Restricted Subsidiary to:

(1)

(A) pay dividends or make any other distributions on its Capital Stock to the Company, TCP or any of their Restricted Subsidiaries, or with respect to any other interest or participation in, or measured by, its profits; or

(B) pay any indebtedness owed to the Company, TCP or any of their Restricted Subsidiaries;

(2) make loans or advances to the Company, TCP or any of their Restricted Subsidiaries; or

(3) sell, lease or transfer any of its properties or assets to the Company, TCP or any of their Restricted Subsidiaries.

(b) The restrictions in Section 4.07(a) will not apply to encumbrances or restrictions existing under or by reason of:

(1) agreements or instruments governing existing Indebtedness as in effect on the Notes Issue Date and any amendments, restatements, modifications, increases, renewals, supplements, refundings, replacements or refinancings of those agreements or instruments; provided that, the amendments, restatements, modifications, increases, renewals, supplements, refundings, replacements or refinancings are no more restrictive, taken as a whole, with respect to such dividend and other payment restrictions than those contained in those agreements or instruments on the Notes Issue Date;

(2) the Finance Documents;

(3) applicable law, rule, regulation or order;

(4) customary non-assignment provisions in contracts and licenses entered into in the ordinary course of business;

(5) purchase money obligations for property acquired in the ordinary course of business and capital lease obligations that impose restrictions on the property purchased or leased;

(6) any agreement for the sale or other disposition of a Restricted Subsidiary that restricts distributions by that Restricted Subsidiary pending the sale or other disposition;

 

74


(7) Indebtedness permitted pursuant to Section 4.08, including Replacement Senior Debt; provided that in the case of Replacement Senior Debt the restrictions contained in the agreements governing such Replacement Senior Debt are not materially more restrictive, taken as a whole, than those contained in the agreements governing the Indebtedness being refinanced;

(8) Liens permitted to be incurred pursuant to Section 4.14 that limit the right of the debtor to dispose of the assets subject to such Liens;

(9) provisions limiting the disposition or distribution of assets or property in joint venture agreements, asset sale agreements, sale-leaseback agreements, stock sale agreements, security agreements, mortgages, purchase money agreements and other similar agreements or instruments entered into with the approval of the Board of Directors (or equivalent governing body) of the Company, TCP, the Pledgor or the applicable Restricted Subsidiary, which limitation is applicable only to the assets that are the subject of such agreements;

(10) Permitted Hedging Instruments; or

(11) restrictions on cash or other deposits or net worth imposed by customers under contracts entered into in the ordinary course of business.

Section 4.08 Limitation on Indebtedness.

Each of the Company and TCP will not and will not permit any of its respective Restricted Subsidiaries to incur Indebtedness or to issue preferred stock; provided that, the Company and any Guarantor may incur any of the following:

(a) Senior Debt, including the Initial Senior Debt and any Additional Senior Debt, incurred in accordance with Section 4.09;

(b) Indebtedness expressly contemplated by a Finance Document to which the Trustee is a party (including guarantees permitted by Section 4.25);

(c) Indebtedness incurred in the ordinary course of business pursuant to a Material Project Agreement;

(d) Subordinated Debt;

(e) intercompany Indebtedness between or among the Company, TCP and any of their respective Restricted Subsidiaries (unless in the case of TCP and its Subsidiaries, a Permitted Pipeline Sale has occurred, in which case, no such intercompany Indebtedness between the Company or any of its Restricted Subsidiaries on the one hand, and TCP or any of its Subsidiaries, on the other hand, shall be permitted under this clause (e)); provided, however, that:

(1) if the Company or any Guarantor is the obligor on such Indebtedness and the payee is not the Company or a Guarantor, such Indebtedness must be unsecured and expressly subordinated to the prior payment in full in cash of all Senior Debt Obligations then due with respect to the Notes, in the case of the Company, or the Note Guarantee, in the case of a Guarantor; and

 

75


(2)

(A) any subsequent issuance or transfer of Equity Interests that results in any such Indebtedness being held by a Person other than the Company, TCP or a Restricted Subsidiary of the Company or TCP; and

(B) any sale or other transfer of any such Indebtedness to a Person that is not either the Company, TCP or a Restricted Subsidiary of the Company or TCP,

will be deemed, in each case, to constitute an incurrence of such Indebtedness by the Company, TCP or such Restricted Subsidiary, as the case may be, that was not permitted by this clause (e);

(f) Indebtedness incurred under Permitted Hedging Instruments not covered under clause (a);

(g) Indebtedness in respect of any bankers’ acceptances, letters of credit, warehouse receipts or similar facilities, in each case, incurred in the ordinary course of business;

(h) purchase money Indebtedness and capital leases or guarantees of the same, in a principal amount not exceeding $100,000,000 in the aggregate outstanding at any one time to finance the purchase or lease of assets for the Development other than those financed with the proceeds of Senior Debt; provided that, if such obligations are secured, they are secured only by Liens upon the assets being financed;

(i) other unsecured Indebtedness in an aggregate amount not to exceed $200,000,000 for general corporate purposes, including all Permitted Refinancing Indebtedness thereof;

(j) other unsecured Indebtedness in an aggregate amount not to exceed $400,000,000 to finance Debottlenecking Expenditures or an Expansion, including all Permitted Refinancing Indebtedness thereof; provided that the foregoing shall be in addition to any PDE Senior Debt otherwise permitted to be incurred under this Indenture;

(k) to the extent constituting Indebtedness, indebtedness arising from honoring by a bank or other financial institution of a check, draft or similar instrument drawn against insufficient funds in the ordinary course or other cash management services in the ordinary course of business;

(l) Indebtedness in respect of netting services, overdraft protections and otherwise in connection with deposit accounts;

(m) contingent liabilities incurred in the ordinary course of business, including the acquisition or sale of goods, services, supplies or merchandise in the normal course of business, the endorsement of negotiable instruments received in the normal course of business and indemnities provided under any of the Finance Documents or Material Project Agreements;

 

76


(n) to the extent constituting Indebtedness, obligations in respect of performance bonds, bid bonds, appeal bonds, surety bonds, indemnification obligations, obligations to pay insurance premiums, take-or-pay obligations contained in supply agreements and similar obligations incurred in the ordinary course of business;

(o) trade debt, trade accounts, purchase money obligations or other similar Indebtedness incurred in the ordinary course of business, which (i) is not more than 90 days past due or (ii) is being contested in good faith and by appropriate proceedings;

(p) Indebtedness in an amount not to exceed $250,000,000 to finance restoration of the Development following damage, loss or destruction of all or a material portion of the Project Facilities or an Event of Taking, including any refinancing thereof; and

(q) Indebtedness consisting of the financing of insurance premiums in customary amounts consistent with the operations and business of the Company, TCP and their Restricted Subsidiaries in the ordinary course of business.

For purposes of determining compliance with this Section 4.08, in the event that an item of Indebtedness meets the criteria of more than one of the categories of Indebtedness permitted pursuant to the paragraphs (a) through (q) of this covenant, the Company will be permitted to classify or divide such item of Indebtedness on the date of its incurrence, or later reclassify or redivide all or a portion of such item of Indebtedness, in any manner that complies with this covenant. The accrual of interest, the accretion or amortization of original issue discount, the payment of interest on any Indebtedness in the form of additional Indebtedness with the same terms, or the reclassification of preferred stock as Indebtedness due to a change in accounting principles will not be deemed to be an incurrence of Indebtedness for purposes of this covenant; provided, that in each such case, the amount of any such accrual, accretion or payment of Indebtedness constituting Senior Debt is included in Senior Debt Obligations of the Company as accrued. Notwithstanding any other provision of this covenant, the maximum amount of Indebtedness that the Company, TCP or any Restricted Subsidiary may incur pursuant to this covenant shall not be deemed to be exceeded solely as a result of fluctuations in exchange rates or currency values.

The amount of any Indebtedness outstanding as of any date will be:

(a) the accreted value of the Indebtedness, in the case of any Indebtedness issued with original issue discount; and

(b) in respect of Indebtedness of another Person secured by a Lien on the assets of the specified Person, the least of:

(1) the Fair Market Value of such asset at the date of determination;

(2) the amount of the Indebtedness of the other Person; and

(3) the principal amount of the Indebtedness, in the case of any other Indebtedness.

 

77


Section 4.09 Incurrence of Senior Debt.

(a) Working Capital Debt. For so long as no Event of Default or Unmatured Event of Default has occurred and is Continuing or would occur after giving effect to the incurrence of the Working Capital Debt, the Company may incur Working Capital Debt in an amount that, at any point in time, does not in the aggregate exceed the sum of (a) $250,000,000 plus (b) the aggregate amount of working capital that the Company reasonably expects will need to be available to the Development (including pursuant to letters of credit) in order to purchase, transport or store Gas and/or meet credit support requirements under Gas purchase, transport or storage agreements in order to supply the LNG amounts contemplated under all LNG SPAs then in effect, plus (c) an amount equivalent to the then-applicable Senior Facilities Reserve Amount required to be deposited in the Senior Facilities Debt Service Reserve Account pursuant to Section 4.5(i) of the CSAA or, if no such amount is then required, an amount equivalent to the Senior Facilities Reserve Amount that is reasonably expected to be required in respect of such Senior Debt, plus (d) an amount equivalent to the then-applicable amount required to be deposited in any Additional Debt Service Reserve Account.

In connection with the incurrence of any Working Capital Debt:

(1) the provider of Working Capital Debt (or a Senior Creditor Group Representative on its behalf) that is secured shall accede as a Senior Creditor to the CSAA and the Common Terms Agreement and the Intercreditor Agreement, if such agreements are still outstanding, and shall share pari passu in the Collateral; and

(2) in respect of Working Capital Debt that is secured, the Intercreditor Agent shall have received a certificate from an Authorized Officer at least three Business Days prior to the incurrence of such Working Capital Debt that (i) identifies each Senior Creditor Group Representative for, and each holder of, any such Working Capital Debt, and (ii) attaches a copy of each proposed Senior Debt Instrument relating to any such Working Capital Debt.

(b) Replacement Senior Debt. At any time and from time to time, the Company may incur replacement senior debt and replacement unsecured debt (collectively, “Replacement Senior Debt”), so long as:

(1) in the case of any Replacement Senior Debt to be incurred following the occurrence of the Project Completion Date (as defined in the Common Terms Agreement), Senior Debt (excluding Working Capital Debt and excluding all Indebtedness under Permitted Senior Debt Hedging Instruments) outstanding after giving effect to the incurrence of the Replacement Senior Debt is capable of being amortized to a zero balance by the termination date of the last to terminate of the Qualifying Indenture LNG SPAs then in effect and produces a Projected Fixed DSCR of at least 1.40:1.00 for the period commencing on the first Indenture Payment Date to occur after the date of incurrence of such Replacement Senior Debt) through the terms of such Qualifying Indenture LNG SPAs (with such ratio being calculated using such Qualifying Indenture LNG SPAs and using an interest rate equal to the weighted average interest rate of Senior Debt (excluding Working Capital Debt) outstanding after giving effect to the incurrence of the Replacement Senior Debt and the prepayment or repayment of the existing Senior Debt or cancellation of the applicable Senior Debt Commitments); and

 

78


(2) in the case of all Replacement Senior Debt, regardless of when incurred, such Replacement Senior Debt is incurred for the permitted refinancing or prepayment in whole or in part of existing Senior Debt including by way of renewal, replacement, redemption or discharge thereof, (and provisions, costs, prepayment premiums, fees or expenses associated with the Replacement Senior Debt or the prepaid Senior Debt, as applicable (including without duplication (i) any Hedging Termination Amount with respect to any Permitted Hedging Instrument subject to the refinancing with the proposed Replacement Senior Debt; (ii) any amounts required to be deposited in a debt service reserve or similar reserve (or any interest during construction) account in connection with the issuance of such Replacement Senior Debt; and (iii) any incremental carrying costs of such Replacement Senior Debt (including any increased interest during construction) associated with any such cancellation, prepayment or redemption, or incurred in connection with the proposed Replacement Senior Debt)), or the permitted replacement of existing unutilized commitments of a Senior Creditor Group (or, within a Senior Creditor Group, of any Facility Lender).

Any provider of secured Replacement Senior Debt (or a Senior Creditor Group Representative on its behalf) will accede as a Senior Creditor to the CSAA and will share pari passu in the Collateral.

(c) Expansion Senior Debt. Following the occurrence of LNG Production System Substantial Completion for LPS2, the Company may incur Senior Debt to finance an Expansion (“Expansion Senior Debt”), so long as each of the following conditions is satisfied and the Company shall have delivered to the Trustee a certificate from an Authorized Officer of the Company certifying that such conditions have been satisfied:

(1) the Company shall have delivered to the Trustee a certificate of an Authorized Officer of the Company certifying that LNG Production System Substantial Completion for LPS2 has occurred;

(2) the design, development, construction and operation of such Expansion is permitted by Section 4.11(a);

(3) no Event of Default or Unmatured Event of Default has occurred and is Continuing;

(4) in the event any mixed refrigerant liquefaction blocks, modules, pretreatment facilities and supporting facilities being financed with the proceeds of such Expansion Senior Debt, any related loading, transportation and storage facilities, any related LNG SPA or any related engineering, construction and procurement (collectively, the “Applicable Expansion Debt Assets”) are not part of the Collateral, prior to the incurrence of such Expansion Senior Debt, the applicable Obligor will deliver such additional agreements and supplements to the Security Documents as are necessary or advisable in order to subject such Applicable Expansion Debt Assets to the Security Interests at the time such Expansion Senior Debt is incurred;

 

79


(5) any Required LNG SPAs are then in effect and there is no material payment default or breach thereunder (or, for any new Required LNG SPA related to LNG to be produced from the Expansion, remain subject only to customary conditions that could be satisfied upon taking an investment decision with respect to the Expansion);

(6) the amount of all Senior Debt (excluding Working Capital Debt and excluding all Indebtedness under Permitted Senior Debt Hedging Instruments) outstanding after giving effect to the incurrence of Expansion Senior Debt is capable of being amortized to a zero balance by the termination date of the last to terminate of the Qualifying Indenture LNG SPAs then in effect and incremental Qualifying Indenture LNG SPAs entered into in respect of sales of LNG associated with the Expansion, and produces a Projected Fixed DSCR of at least 1.40:1.00 for the period commencing on the first Indenture Payment Date to occur after the “facility substantial completion deadline” (as defined in the applicable engineering, procurement and/or construction contracts) or comparable term, in each case, with respect to the Applicable Expansion Debt Assets, through the terms of such Qualifying Indenture LNG SPAs (with such ratio calculated using such Qualifying Indenture LNG SPAs and using an interest rate equal to the weighted average interest rate of Senior Debt (excluding Working Capital Debt) outstanding after giving effect to the incurrence of the Expansion Senior Debt);

(7)

(A) so long as at least $1 billion of Loans or Senior Debt Commitments in connection therewith are outstanding, the Company has obtained the consent of the Facility Lenders pursuant to the Common Terms Agreement if such consent is required under the Common Terms Agreement or a Facility Agreement prior to the incurrence of Expansion Senior Debt; or

(B) the Company has obtained and delivered to the Trustee a Rating Reaffirmation in respect of the Notes on the basis of the incurrence of such Expansion Senior Debt;

(8) the final maturity date of the Expansion Senior Debt is no earlier than the “facility substantial completion deadline” (as defined in the applicable engineering, procurement and/or construction contracts) or comparable term, in each case, with respect to the Applicable Expansion Debt Assets; and

(9) the Expansion Senior Debt does not benefit from any security or guarantee from the Obligors or the Sponsor or its Affiliates (other than cash or letters of credit provided by the Sponsors or their Affiliates to fund the Senior Facilities Debt Service Reserve Account, any Additional Debt Service Reserve Account or any other reserve account required by such Expansion Senior Debt) that is in addition to any security or guarantee from such Persons provided in respect of the Initial Senior Debt unless such security or guarantee is provided for the equal and ratable benefit of each Senior Creditor.

 

80


(d) Permitted Development Expenditure Senior Debt. The Company may incur Senior Debt to finance a Permitted Development Expenditure (“PDE Senior Debt”) so long as each of the following conditions are satisfied and the Company shall have delivered to the Trustee a certificate of an Authorized Officer of the Company certifying that such conditions have been satisfied:

(1) (a) the design, development, construction and operation of such Permitted Development Expenditure is permitted as described under Section 4.10 and (b) the aggregate amount of PDE Senior Debt used or to be used for Permitted Development Expenditures is less than $300,000,000;

(2) no Event of Default or Unmatured Event of Default has occurred and is Continuing;

(3) any Required LNG SPAs are then in effect and there is no material payment default or breach thereunder; and

(4) the PDE Senior Debt does not benefit from any security or guarantee from the Obligors or the Sponsor or its Affiliates that is in addition to any security or guarantee from such Persons provided in respect of the Initial Senior Debt unless such security or guarantee is provided for the equal and ratable benefit of each Senior Creditor.

(e) Additional Senior Debt. The Company may incur additional Senior Debt (“Additional Senior Debt”), so long as each of the following conditions is satisfied and the Company shall have delivered to the Trustee a certificate of an Authorized Officer of the Company certifying that such conditions have been satisfied:

(1) no Event of Default or Unmatured Event of Default has occurred and is Continuing;

(2) any Required LNG SPAs are then in effect and there is no material payment default or breach thereunder;

(3) after incurrence of such Additional Senior Debt, Senior Debt (excluding Working Capital Debt and excluding all Indebtedness under Permitted Senior Debt Hedging Instruments) outstanding after giving effect to the incurrence of the Additional Senior Debt is capable of being amortized to a zero balance by the termination date of the last to terminate of the Qualifying Indenture LNG SPAs then in effect and produces a Projected Fixed DSCR of at least 1.40:1.00 for the period commencing on the first Indenture Payment Date to occur after the date of incurrence of such Additional Senior Debt through the terms of such Qualifying Indenture LNG SPAs (with such ratio being calculated using such Qualifying Indenture LNG SPAs and using an interest rate equal to the weighted average interest rate of Senior Debt (excluding Working Capital Debt) outstanding after giving effect to the incurrence of the Additional Senior Debt);

(4) such Additional Senior Debt does not benefit from any security or guarantee from the Obligors or the Sponsors or their Affiliates (other than cash or letters of credit provided by the Sponsors or their Affiliates to fund the Senior Facilities Debt Service Reserve Account, any Additional Debt Service Reserve Account or any other reserve account required by such Additional Senior Debt) that is in addition to any security or guarantee from such Persons provided in respect of the Initial Senior Debt unless such security or guarantee is provided for the equal and ratable benefit of each Senior Creditor; and

 

81


(5) such Additional Senior Debt is permitted to be incurred under all Senior Debt Instruments then in effect and subject to the terms and conditions in such Senior Debt Instruments to the incurrence of such Additional Senior Debt.

Section 4.10 Permitted Development Expenditures.

The Company, TCP and any of their respective Restricted Subsidiaries may make Development Expenditures that qualify as Permitted Development Expenditures that qualify as such in accordance with the applicable definition thereof. In addition, for the avoidance of doubt, a Development Expenditure may also be made in connection with an Expansion or as a result of permitted modifications of an engineering, procurement and construction contract.

Section 4.11 Expansions.

(a) Expansions. The Company, TCP and any of their respective Restricted Subsidiaries, subject to satisfaction of the conditions set forth in Section 4.11(b) below, will have the right to modify existing facilities, and to construct the following additional facilities, including acquiring land for the location of such additional facilities:

(1) any mixed refrigerant liquefaction blocks, modules, pretreatment facilities and supporting facilities in addition to the LNG Facilities and related storage, transportation, loading, unloading and other facilities and equipment;

(2) other facilities for producing, storing, loading or unloading LNG or other products required for or associated with the production of LNG;

(3) expansion of existing pipelines or construction of new pipelines, and related infrastructure;

(4) other modifications of then-existing Project Facilities; and

(5) the construction of Project Facilities or other infrastructure pursuant to a Sharing Arrangement permitted under Section 4.28;

(such expansions and/or modifications, which, in the aggregate, are in excess of $50,000,000 (and which in each case are not Debottlenecking Expenditures) are referred to as “Expansions” and each an “Expansion”); provided that, notwithstanding the conditions set forth in Section 4.11(b) below, the Company, TCP and any of their respective Restricted Subsidiaries may at any time after LNG Production System Substantial Completion for LPS1 (a) conduct front- end engineering, development and design work using Equity Funding; (b) prepare and submit applications for Permits related to any such Expansion; (c) undertake early works and/or pre- construction activities; and (d) enter into a construction contract or construction contracts with respect to the development of mixed refrigerant liquefaction blocks, modules, pretreatment facilities and supporting facilities in addition to the LNG Facilities, and related loading, transportation and storage facilities, that contain obligations and liabilities not exceeding $300,000,000.

 

82


(b) Conditions to Expansion. The Company, TCP and any of their respective Restricted Subsidiaries may exercise their foregoing rights in relation to an Expansion if the following conditions are satisfied and the Company shall have delivered to the Trustee a certificate from an Authorized Officer of the Company certifying that such conditions have been satisfied:

(1) the Company has provided to the Trustee a funding plan covering the full amount of costs in respect thereof in order to achieve substantial completion of the mixed refrigerant liquefaction blocks, modules, pretreatment facilities and supporting facilities, and related loading, transportation and storage facilities comprising the Expansion, a budget and construction schedule of the Expansion, with an appropriate contingency and identifying the source of funds to cover such costs (being permitted Expansion Senior Debt, additional funding (including contributions in the form of Subordinated Debt or Equity Funding) from the Sponsor under an equity commitment agreement (“Expansion Equity Funding Commitment”) and/or Development-generated funds that are projected by the Company to be freely available for Restricted Payments as set forth in sub-clause (6)(C) below);

(2) the Company shall have delivered to the Trustee a certificate from an Authorized Officer of the Company certifying that no Material Adverse Effect will occur, or would reasonably be expected to occur, as a result of the implementation of such proposed Expansion (including, without limitation, the construction, ownership or operation thereof);

(3) the Independent Engineer shall have certified to the Trustee that it has reviewed and concurs with the Company’s cost estimate under clause (1) above and the Company’s certification in clause (2) above;

(4) the Company shall have delivered to the Trustee a certificate from an Authorized Officer of the Company certifying that:

(A) all material Permits from a Governmental Authority required in respect of the implementation of such proposed Expansion (excluding any FERC order or Export Authorizations which are addressed in sub-clauses (B) and (C) below) have been obtained or the Company shall have delivered to the Trustee a certificate from an Authorized Officer of the Company certifying that it reasonably expects such material consents can be obtained by the Obligors when necessary without material expense or delay to construction of the Expansion;

(B) a FERC order with respect to the Expansion: (i) has been obtained (ii) is in full force and effect, and (iii) is free from conditions and requirements (y) the compliance with which could reasonably be expected to have a Material Adverse Effect or (z) that the applicable Obligor does not expect to be able to satisfy on or prior to the commencement of the relevant stage of the development of the Expansion except to the extent that failure to satisfy such condition or requirement would not reasonably be expected to have a Material Adverse Effect;

 

83


(C) to the extent an Expansion relates to additional LNG production, each Export Authorization in respect of the quantum of sales contemplated in connection with the Expansion: (i) has been obtained, (ii) is in full force and effect and (iii) is free from conditions and requirements (y) the compliance with which could reasonably be expected to have a Material Adverse Effect or (z) that the applicable Obligor does not expect to be able to satisfy on or prior to the commencement of the relevant stage of the development of the Expansion except to the extent that failure to satisfy such condition or requirement would not reasonably be expected to have a Material Adverse Effect;

(D) the Company has used reasonable commercial efforts to obtain insurance with respect to the proposed Expansion consistent with the requirements of Section 4.23 taking into account the type and value of the Expansion; and

(E) the engineering, procurement and construction contracts associated with the proposed Expansion are in effect and no material payment default exists thereunder;

(5) no Event of Default or Unmatured Event of Default has occurred and is Continuing;

(6) if the funding plan delivered under clause (1) above for any Expansion contemplates that:

(A) Expansion Senior Debt is a source of funding, then (i) such Senior Debt is permitted under Section 4.09(c) and Section 4.09(d) and (ii) the cost of such Expansion that is not covered (if applicable) by Expansion Senior Debt is covered by Expansion Equity Funding Commitments as described in sub-clause (B) below and/or Development-generated funds meeting the requirements under sub-clause (C) below;

(B) Expansion Equity Funding Commitments are a source of funding, then the commitment of the Sponsor to provide such Expansion Equity Funding Commitments is set forth in an irrevocable equity commitment agreement and the Company’s rights under such funding commitments have been assigned to the Collateral Agent for the benefit of the Senior Creditors, and the Obligors have obtained a direct agreement with the Collateral Agent in respect of each such funding commitment from the entity providing such funding commitment; and

(C) Development-generated funds are a source of funding, then such funds are projected by the Company to be freely available for Restricted Payments (taking into account the condition to the making of Restricted Payments in Section 4.06(b)(2), but no others), such projection to be detailed, based on reasonable assumptions and certified by an Authorized Officer to the Trustee. This certification will not require any further determination by the Trustee.

 

84


Section 4.12 Asset Sales.

(a) The Pledgor will not, and each of the Company and TCP will not, and will not permit any of its respective Restricted Subsidiaries to, consummate an Asset Sale unless each of the following conditions is satisfied and the Company shall have delivered to the Trustee a certificate of an Authorized Officer of the Company certifying that such conditions have been satisfied:

(1) The Pledgor, the Company or TCP (or the Restricted Subsidiary, as the case may be) receives consideration at the time of the Asset Sale equal to the Fair Market Value of the assets or Equity Interests issued or sold or otherwise disposed of; and

(2) at least 90% of the consideration therefor received by the Pledgor, the Company, TCP or such Restricted Subsidiary, as the case may be, is in the form of cash, Authorized Investments or Replacement Assets or a combination thereof. For purposes of this provision, each of the following will be deemed to be cash:

(A) any liabilities, as shown on the most recent consolidated balance sheet (or as would be shown on the consolidated balance sheet as of the date of such Asset Sale) of the Company, TCP or any Restricted Subsidiary (other than contingent liabilities and liabilities that are by their terms subordinated to the Notes or any Note Guarantee) that are assumed by the transferee of any such assets pursuant to a written novation agreement that releases the Company, TCP or such Restricted Subsidiary from further liability therefor; and

(B) any securities, Notes or other obligations received by the Company, TCP or such Restricted Subsidiary from such transferee that are converted by the Company, TCP or such Restricted Subsidiary into cash or Authorized Investments within 90 days after such Asset Sale, to the extent of the cash or Authorized Investments received in that conversion.

The Net Cash Proceeds of any Permitted Pipeline Sale shall be contributed as equity or via an intercompany loan (to the extent not otherwise prohibited under Section 4.08) by the Pledgor to the Company, and neither TCP nor any of its Restricted Subsidiaries shall be released as a Guarantor and no applicable Security Interests shall be released in accordance Section 11.05 until such Net Cash Proceeds shall have been so contributed.

(b) Within 360 days after the receipt of any Net Cash Proceeds from an Asset Sale, the Company or TCP (or the applicable Restricted Subsidiary, as the case may be) may apply an amount equal to such Net Cash Proceeds:

(1) to repay any Senior Debt in accordance with the applicable Senior Debt Instrument; or

(2) to make any capital expenditure or to purchase Replacement Assets (or enter into a binding agreement to make such capital expenditure or to purchase such Replacement Assets); provided that (i) such capital expenditure or purchase is consummated within the later of (x) 360 days after the receipt of the Net Cash Proceeds from the related Asset Sale and (y) 180 days after the date of such binding agreement and (ii) if such capital expenditure or purchase is not consummated within the period set forth in subclause (i), the amount not so applied will be deemed to be Excess Proceeds.

 

85


(c) Pending the final application of any Net Cash Proceeds, the Company, TCP or the applicable Restricted Subsidiary may reduce Working Capital Debt or other revolving credit borrowings or otherwise invest the Net Cash Proceeds in any manner that is not prohibited by this Indenture.

(d) An amount equal to any Net Cash Proceeds from Asset Sales that are not applied or invested as provided in the preceding paragraphs of this Section 4.12 will constitute “Excess Proceeds.” If, on any date, the aggregate amount of Excess Proceeds exceeds $300,000,000, then within ten Business Days after such date, the Company will make an Asset Sale Offer in accordance with Section 3.09. The offer price or prepayment amount in any Asset Sale Offer will be equal to 100% of the principal amount of the Notes plus accrued and unpaid interest, if any, to, but excluding, the date of purchase, and will be payable in cash. If any Excess Proceeds remain unapplied after consummation of an Asset Sale Offer, the Company, TCP and their Restricted Subsidiaries may use those Excess Proceeds for any purpose not otherwise prohibited by this Indenture. Upon completion of each Asset Sale Offer, the amount of Excess Proceeds will be reset at zero.

(e) Notwithstanding the foregoing, other than in connection with a Permitted Pipeline Sale, the sale, conveyance or other disposition of all or substantially all of the assets of the Company, TCP and their respective Restricted Subsidiaries, taken as a whole, will be governed by the provisions of Section 5.01 and not by the provisions of this Section 4.12.

(f) The Company will comply with the requirements of Rule 14e-1 under the Exchange Act and any other securities laws and regulations thereunder to the extent such laws and regulations are applicable in connection with each repurchase of Notes pursuant to an Asset Sale Offer. To the extent that the provisions of any securities laws or regulations conflict with the provisions of Section 3.09 or this Section 4.12, or compliance with the provisions of Section 3.09 or this Section 4.12 would constitute a violation of any such laws or regulations, the Company will comply with the applicable securities laws and regulations and will not be deemed to have breached its obligations under Section 3.09 or this Section 4.12 by virtue of such compliance.

(g) If the Trustee, on behalf of the Holders, receives any Net Cash Proceeds to be applied to the prepayment of Senior Debt and this Indenture does not require the Company to make an Asset Sale Offer pursuant to this Section 4.12, the Company shall instruct the Trustee to deposit such proceeds in the Construction Account or the Revenue Account, as applicable, and the Trustee shall be required to make such deposit.

(h) Pending their application, all Net Cash Proceeds while held by the Company in an Account will be invested as Authorized Investments in which the Collateral Agent has a perfected Security Interest for the benefit of the Secured Parties, subject only to Permitted Liens. The Company and TCP, as applicable, will grant to the Collateral Agent, on behalf of the Secured Parties, a security interest, subject only to Permitted Liens, on any property or assets purchased, rebuilt, repaired, replaced or constructed with such Excess Proceeds on the terms set forth in this Indenture and the Security Documents.

 

86


Section 4.13 Transactions with Affiliates.

Each of the Company and TCP will not and will not permit any of its respective Restricted Subsidiaries to, directly or indirectly, enter into any transaction or agreement with or for the benefit of any of their Affiliates involving aggregate payments or consideration in excess of $50,000,000 except for:

(a) transactions or agreements required by applicable law or regulation;

(b) transactions or agreements required or contemplated by the CSAA;

(c) transactions or agreements contemplated by any Material Project Agreement and entered into in the ordinary course of business (but not the entering into of a Material Project Agreement or an agreement that, pursuant to the terms of this Indenture, becomes a Material Project Agreement);

(d) transactions or agreements undertaken on fair and commercially reasonable terms that are not less favorable in the aggregate to the Company, TCP or such Restricted Subsidiary than would be obtained in a comparable agreement with independent parties acting at arm’s length (or, if there is no comparable arm’s-length transaction, then on terms reasonably determined by the Board of Directors (or equivalent governing body) of the Company or TCP to be fair and reasonable);

(e) transactions or agreements between or among the Company, TCP and/or their Restricted Subsidiaries; provided that, this clause (e) shall not apply to any transactions or agreements between or among the Company and/or its Restricted Subsidiaries, on the one hand, and TCP and/or its Subsidiaries, on the other hand, entered into following or in contemplation of a Permitted Pipeline Sale;

(f) Subordinated Debt between or among the Company, TCP and/or their Restricted Subsidiaries and any of their Affiliates (unless in the case of TCP and its Subsidiaries, a Permitted Pipeline Sale has occurred, in which case, no such Subordinated Debt between the Company or any of its Restricted Subsidiaries, on the one hand, and TCP or any of its Subsidiaries, on the other hand, shall be permitted under this clause (f));

(g) any Sharing Arrangement with an Affiliate of the Company or TCP; provided, that the terms of such agreement provide for the recovery by the Company, TCP or their respective Restricted Subsidiaries, as the case may be, of at least the incremental Operation and Maintenance Expenses associated with operations pursuant to such agreement and the Company, TCP or such Restricted Subsidiary has entered into the required Security Documents in respect of its rights under such agreements; provided further that, this clause (g) shall not apply to any Sharing Arrangement between or among the Company and/or its Restricted Subsidiaries, on the one hand, and TCP and/or its Subsidiaries, on the other hand, entered into following or in contemplation of a Permitted Pipeline Sale;

 

87


(h) any employment agreement, employee benefit plan, officer or director indemnification agreement or any similar arrangement entered into by the Company, TCP or a Restricted Subsidiary, as the case may be, in the ordinary course of business and payments pursuant thereto;

(i) transactions with a Person (other than (i) an Unrestricted Subsidiary of the Company or TCP or (ii) a Permitted Pipeline Sale, TCP or any Affiliate of TCP) that is an Affiliate of the Company or TCP solely because the Company or TCP owns, directly or through a Restricted Subsidiary, an Equity Interest in, or controls, such Person;

(j) any issuance of Equity Interests (other than Disqualified Stock) of the Company or TCP to Affiliates of the Company or TCP; provided that, this clause (j) shall not apply to any issuance of Equity Interests of the Company to TCP following or in contemplation of a Permitted Pipeline Sale;

(k) Permitted Investments permitted under Section 4.18 or Restricted Payments permitted under Section 4.06;

(l) Permitted Payments;

(m) any contracts, agreements or understandings existing as of the Notes Issue Date or disclosed in the Offering Memorandum, and any amendments to or replacements of such contracts, agreements or understandings permitted under the Finance Documents to which the Trustee is a party;

(n) any arrangements entered into in accordance with the provisions in Section 4.27 and Section 4.28; and

(o) a Permitted Pipeline Sale.

Prior to entering into any agreement with an Affiliate pursuant to clause (d) above, and involving aggregate consideration in excess of $50,000,000, the Company shall deliver to the Trustee a certificate from an Authorized Officer of the Company as to the satisfaction of the applicable condition set forth in such clause (d).

Section 4.14 Liens.

Subject to Section 3 of the CSAA, each of the Company and TCP will not and will not permit any of its respective Restricted Subsidiaries to assume, incur, permit or suffer to exist any Lien on any of their assets, whether now owned or hereafter acquired, except for Permitted Liens.

Section 4.15 Nature of Business.

Each of the Company and TCP will not, and will not permit any of its respective Restricted Subsidiaries to engage in any business or activities other than the Permitted Businesses, except to such extent as would not be material to the Company, TCP and their Restricted Subsidiaries, taken as a whole.

 

88


Section 4.16 Maintenance of Existence.

Subject to Section 5.01, the Company and each Guarantor shall do all things necessary to maintain: (a) its corporate, limited liability company or partnership, as applicable, existence in its jurisdiction of organization; provided that the foregoing shall not prohibit conversion into another form of entity or continuation in another jurisdiction and (b) the power and authority (corporate and otherwise) necessary under the applicable law to own its properties and to carry on the business of the Development. Each of the Company and the Guarantors shall not dissolve, liquidate, and shall not take any action to amend or modify its corporate constituent or governing documents where such amendment would be adverse in any material respect to the Holders.

Section 4.17 Change of Control.

(a) If a Change of Control Triggering Event occurs and the exceptions set forth in Section 4.17(e) do not apply, the Company will be required to make an offer to repurchase all of the Notes (a “Change of Control Offer”) for payment (a “Change of Control Payment”) in cash equal to 101% of the aggregate principal amount of the Notes repurchased, plus accrued and unpaid interest, if any, to the date of repurchase (“Change of Control Payment Date,” which date will be no earlier than the date of the corresponding Change of Control). No later than 30 days following any Change of Control, the Company will deliver a notice to each Holder describing the transaction or transactions that constitute the Change of Control and stating:

(1) that the Change of Control Offer is being made pursuant to this Section 4.17 and that all Notes tendered will be accepted for payment;

(2) the purchase price and the purchase date, which shall be no earlier than 30 days and no later than 60 days from the date such notice is delivered;

(3) that any Note not tendered will continue to accrete or accrue interest;

(4) that, unless the Company defaults in the payment of the Change of Control Payment, all Notes accepted for payment pursuant to the Change of Control Offer will cease to accrete or accrue interest after the Change of Control Payment Date;

(5) that Holders electing to have any Notes purchased pursuant to a Change of Control Offer will be required to surrender the Notes, with the form entitled “Option of Holder to Elect Purchase” attached to the Notes completed, or transfer by book-entry transfer, to the Paying Agent at the address specified in the notice prior to the close of business on the third Business Day preceding the Change of Control Payment Date;

(6) that Holders will be entitled to withdraw their election if the Paying Agent receives, not later than the close of business on the second Business Day preceding the Change of Control Payment Date, a telegram, telex, facsimile transmission or letter setting forth the name of the Holder, the principal amount of Notes delivered for purchase, and a statement that such Holder is withdrawing his election to have the Notes purchased; and

(7) that Holders whose Notes are being purchased only in part will be issued new Notes equal in principal amount to the unpurchased portion of the Notes surrendered, which unpurchased portion must be equal to $2,000 in principal amount or an integral multiple of $1,000 in excess thereof.

 

89


The Company will comply with the requirements of Rule 14e-1 under the Exchange Act and any other securities laws and regulations thereunder to the extent such laws and regulations are applicable in connection with the repurchase of the Notes as a result of a Change of Control. To the extent that the provisions of any securities laws or regulations conflict with this Section 4.17, or compliance with this Section 4.17 would constitute a violation of any such laws or regulations, the Company will comply with the applicable securities laws and regulations and will not be deemed to have breached its obligations under this Section 4.17 by virtue of such compliance.

(b) On the Change of Control Payment Date, the Company will, to the extent lawful:

(1) accept for payment all Notes or portions of Notes properly tendered pursuant to the Change of Control Offer;

(2) deposit with the Paying Agent an amount equal to the Change of Control Payment in respect of all Notes or portions of Notes properly tendered; and

(3) deliver or cause to be delivered to the Trustee the Notes properly accepted together with an Officer’s Certificate stating the aggregate principal amount of Notes or portions of Notes being purchased by the Company.

The Paying Agent will promptly mail (but in any case not later than five days after the Change of Control Payment Date) to each Holder of Notes properly tendered the Change of Control Payment for such Notes.

(c) The Company will publicly announce the results of the Change of Control Offer on or as soon as practicable after the Change of Control Payment Date.

(d) If Holders of not less than 90% in aggregate principal amount of the outstanding Notes validly tender and do not withdraw such Notes in a Change of Control Offer and the Company, or any third party making a Change of Control Offer in lieu of the Company as described below, purchases all of the Notes validly tendered and not withdrawn by such Holders, the Company will have the right, upon not less than 30 nor more than 60 days’ prior notice, given not more than 30 days following such purchase pursuant to the Change of Control Offer described above, to redeem all Notes that remain outstanding following such purchase at a redemption price in cash equal to the applicable Change of Control Payment plus, to the extent not included in the Change of Control Payment, accrued and unpaid interest, if any, to the date of redemption.

(e) Notwithstanding anything to the contrary in this Section 4.17, the Company will not be required to make a Change of Control Offer upon a Change of Control if (1) a third party makes the Change of Control Offer in the manner, at the times and otherwise in compliance with the requirements set forth in this Section 4.17 and purchases all Notes properly tendered and not withdrawn under the Change of Control Offer, or (2) notice of redemption has been given pursuant to Section 3.03 with respect to a redemption of Notes pursuant to Section 3.07, unless and until there is a default in payment of the applicable redemption price.

 

90


(f) If the Change of Control Payment Date is on or after an interest record date but on or prior to the related interest payment date, then any accrued and unpaid interest shall be paid to the Person in whose name such note was registered at the close of business on such record date.

Section 4.18 Limitation on Investments and Loans.

Each of the Company and TCP will not and will not permit any of its respective Restricted Subsidiaries to make any Investments other than Permitted Investments.

Section 4.19 Events of Loss.

(a) If an Event of Loss (other than a Catastrophic Casualty Event) has occurred, Insurance Proceeds and Condemnation Proceeds, as applicable, received by the Company, TCP or any Restricted Subsidiary as a result thereof will be applied to rebuilding, repairing, replacing or constructing improvements to the Project Facilities, with no obligation to make any purchase of Notes.

(b) If an Event of Loss is a Catastrophic Casualty Event, then within 120 days following the Catastrophic Casualty Event, the Company will deliver to the Trustee:

(1) a written confirmation from a reputable contractor or engineer that the Project Facilities can be rebuilt, repaired, replaced or constructed and operating within 540 days following the time such proceeds are received; and

(2) a certificate from an Authorized Officer certifying that the applicable entity has available from Insurance Proceeds or Condemnation Proceeds, as applicable, cash on hand, projected Cash Flow taking into account the impact of such event, binding equity commitments with respect to funds, anticipated insurance proceeds and/or available borrowings under Indebtedness permitted under Section 4.08 to complete the rebuilding, repair, replacement or construction described in sub-clause (a) above of this Section 4.19 and to pay debt service on its Indebtedness during the repair and restoration period.

(c) If a Catastrophic Casualty Event has occurred, but (i) the confirmation in Section 4.19(b)(1) and Section 4.19(b)(2) is not provided within the required 120 days or (ii) if provided, any Insurance Proceeds or Condemnation Proceeds received in connection therewith are not reinvested (or committed for investment by the Company, TCP or any Restricted Subsidiary) within the required 540 days, such proceeds will be deemed “Excess Loss Proceeds.”

(d) If on any date the aggregate amount of Excess Loss Proceeds exceeds $500,000,000, then within 15 Business Days after such date, the Company will make an Excess Loss Proceeds Offer in accordance with Section 3.09. Such purchase, redemption or repayment will be subject to the pro rata payment provisions in the CSAA. The offer price or prepayment amount in any Excess Loss Proceeds Offer will be equal to 100% of the principal amount of the Notes plus accrued but unpaid interest, if any, to, but excluding, the date of purchase, and will be payable in cash. If any Excess Loss Proceeds remain unapplied after consummation of an Excess Loss Proceeds Offer, the Company, TCP and their Restricted Subsidiaries may use those Excess Proceeds for any purpose not otherwise prohibited by this Indenture. Upon completion of each Excess Loss Proceeds Offer, the amount of Excess Loss Proceeds will be reset at zero.

 

91


(e) The Company will comply with the requirements of Rule 14e-1 under the Exchange Act and any other securities laws and regulations thereunder to the extent such laws and regulations are applicable in connection with each repurchase of Notes pursuant to an Excess Loss Proceeds Offer. To the extent that the provisions of any securities laws or regulations conflict with the provisions of Section 3.09 or this Section 4.19, or compliance with the provisions of Section 3.09 or this Section 4.19 would constitute a violation of any such laws or regulations, the Company will comply with the applicable securities laws and regulations and will not be deemed to have breached its obligations under Section 3.09 or this Section 4.19 by virtue of such compliance.

(f) If the Trustee, on behalf of the Holders, receives any Insurance Proceeds or Condemnation Proceeds applied to the prepayment of Senior Debt and this Indenture does not require the Company to make an Excess Loss Proceeds Offer pursuant to this Section 4.19, the Company shall instruct the Trustee to deposit such proceeds in the Construction Account or the Revenue Account, as applicable, and the Trustee shall be required to make such deposit.

(g) Pending their application, all Insurance Proceeds and Condemnation Proceeds while held by the Company in an Account will be invested as Authorized Investments in which the Collateral Agent has a perfected Security Interest for the benefit of the Secured Parties, subject only to Permitted Liens. The Company and TCP will grant to the Collateral Agent, on behalf of the Secured Parties, a security interest, subject only to Permitted Liens, on any property or assets purchased, rebuilt, repaired, replaced or constructed with such Insurance Proceeds and Condemnation Proceeds on the terms set forth in this Indenture and the Security Documents.

Section 4.20 Performance Liquidated Damages.

(a) If no Loans or Senior Debt Commitments in connection therewith are outstanding and the Company, TCP or a Restricted Subsidiary has received Performance Liquidated Damages, it shall use such Performance Liquidated Damages, within the later of (i) 30 days following the date on which the Facility Substantial Completion occurs and (ii) 270 days following receipt thereof (or 360 days if a commitment to complete, repair, refurbish or improve the Project Facilities is entered within 270 days following the receipt of such proceeds) to:

(1) complete, repair, refurbish or improve the Project Facilities in respect of which the Performance Liquidated Damages were paid or other Project Facilities under construction; or

(2) repay or reimburse providers of Equity Funding to the extent such Equity Funding was used to complete, repair, refurbish or improve the Project Facilities in respect of which the Performance Liquidated Damages were paid or other Project Facilities under construction.

(b) Any Performance Liquidated Damages that are not applied in the manner and within the time periods set forth in the foregoing paragraph will be deemed “PLD Excess Proceeds.”

 

92


(c) If on any date the aggregate amount of PLD Excess Proceeds exceeds $100,000,000, then within ten Business Days after such date, the Company shall make a PLD Excess Proceeds Offer in accordance with Section 3.09. The offer price in any PLD Excess Proceeds Offer will be equal to 100% of the principal amount of the Notes of each series, plus accrued but unpaid interest, if any, to, but excluding the date of purchase, and will be payable in cash. If any PLD Excess Proceeds remain after consummation of a PLD Excess Proceeds Offer, the Company may use those PLD Excess Proceeds for any purpose not otherwise prohibited by this Indenture. Upon completion of each PLD Excess Proceeds Offer, the amount of PLD Excess Proceeds for the purposes of this paragraph will be reset at zero.

(d) The Company will comply with the requirements of Rule 14e-1 under the Exchange Act and any other securities laws and regulations thereunder to the extent such laws and regulations are applicable in connection with each repurchase of Notes pursuant to a PLD Excess Proceeds Offer. To the extent that the provisions of any securities laws or regulations conflict with the provisions of Section 3.09 or this Section 4.20, or compliance with the provisions of Section 3.09 or this Section 4.20 would constitute a violation of any such laws or regulations, the Company will comply with the applicable securities laws and regulations and will not be deemed to have breached its obligations under Section 3.09 or this Section 4.20 by virtue of such compliance.

(e) If the Trustee, on behalf of the Holders, receives any Performance Liquidated Damages applied to the prepayment of Senior Debt and this Indenture does not require the Company to make a PLD Excess Proceeds Offer pursuant to this Section 4.20, the Company shall instruct the Trustee to deposit such proceeds in the Construction Account or the Revenue Account, as applicable, and the Trustee shall be required to make such deposit.

(f) Pending their application, all Performance Liquidated Damages while held by the Company in an Account will be invested as Authorized Investments in which the Collateral Agent has a perfected Security Interest for the benefit of the Secured Parties, subject only to Permitted Liens. The Company and TCP will grant to the Collateral Agent, on behalf of the Secured Parties, a security interest, subject only to Permitted Liens, on any property or assets purchased, rebuilt, repaired, replaced or constructed with such Performance Liquidated Damages on the terms set forth in this Indenture and the Security Documents.

Section 4.21 LNG SPA Mandatory Offer.

(a) The Company shall make an LNG SPA Mandatory Prepayment as required by the Common Terms Agreement and, for purposes of implementing the pro rata payment of Senior Debt Obligations provisions of the CSAA, if either of the events set forth below occurs (each, an “Indenture LNG SPA Prepayment Event”), the Company will make an LNG SPA Mandatory Offer in accordance with Section 3.09 as set forth below:

(1) The Company breaches the LNG SPA maintenance covenant in Section 4.29; or

(2) with respect to a Required LNG SPA, a Required Export Authorization becomes Impaired and the Company does not (i) provide a remediation plan to the Trustee (setting forth in reasonable detail proposed steps to reinstate the Required Export Authorization or to modify its LNG SPA arrangements such that such Export Authorization is no longer a Required Export Authorization with respect to any or all of such Required LNG SPAs (each such item, an “Export Authorization Remediation”)) within 30 days

 

93


following such Impairment, and (ii) cause such Export Authorization Remediation to become effective within 90 days following the occurrence of such Impairment, which period is automatically extended by an additional 90 days to effect the Export Authorization Remediation if the Company certifies to the Trustee prior to the termination of the initial 90 day period that (A) the Company is diligently pursuing its plan for the Export Authorization Remediation and (B) the Impairment of the Required Export Authorization could not reasonably be expected to result in a Material Adverse Effect during such subsequent cure period; provided that if no Loans or Senior Debt Commitments in connection therewith remain outstanding, the maximum period within which the Company shall effect such Export Authorization Remediation under sub-clause (b)(ii) is 360 days.

(b) To the extent any Loans or Senior Debt Commitments in connection therewith are outstanding and the Intercreditor Agent has approved any extension of the time period in which a remediation plan must be submitted or in which an Export Authorization Remediation must take effect, then the Company shall have the benefit of such extended period under this Indenture to submit such remediation plan or for such Export Authorization Remediation to take effect.

(c) For so long as at least $1 billion of Loans or Senior Debt Commitments in connection therewith are outstanding, the Company shall make an LNG SPA Mandatory Prepayment in accordance with the provisions of the Common Terms Agreement (including an LNG SPA Mandatory Offer in an amount as determined in accordance with the applicable pro rata payment of Senior Debt Obligations provisions of the CSAA) in an amount as determined in accordance with the LNG SPA Mandatory Prepayment provisions of the Common Terms Agreement (such amount, the “LNG SPA Mandatory Prepayment Amount (CTA Calculation)”).

(d) For so long as Loans or Senior Debt Commitments in connection therewith are outstanding but are less than $1 billion, the Company shall make an LNG SPA Mandatory Prepayment in accordance with the provisions of the Common Terms Agreement (including an LNG SPA Mandatory Offer in an amount as determined in accordance with the applicable pro rata payment of Senior Debt Obligations provisions of the CSAA) in an amount (such amount, the “LNG SPA Mandatory Prepayment Amount (CTA/Indenture Calculation)”) equal to the greater of:

(1) the amount of the LNG SPA Mandatory Prepayment as required by the Common Terms Agreement; and

(2) the difference between:

(A) the aggregate principal amount of Senior Debt then outstanding plus the aggregate principal amount of undrawn Facility Debt Commitments, less

(B) the maximum amount of Senior Debt that can be incurred such that it is capable of being amortized to a zero balance through the termination date of the last to terminate of the Qualifying LNG SPAs then in effect (including any Replacement Indenture Qualifying LNG SPAs entered into to replace any LNG SPAs whose termination triggered the Indenture LNG SPA Prepayment Event) and produces a Projected Fixed DSCR of at least 1.40:1.00 through the terms of such Qualifying LNG SPAs, with such calculation using all such Qualifying LNG SPAs in respect of which there is in effect their Required Export Authorizations which are not Impaired, and using an interest rate equal to the weighted average interest rate of all Senior Debt (other than Working Capital Debt) then outstanding.

 

94


(e) For so long as there are no Loans or Senior Debt Commitments in connection therewith outstanding, the Company shall make an LNG SPA Mandatory Offer in accordance with Section 3.09 in an aggregate amount (such amount, the “LNG SPA Mandatory Offer Amount”) equal to:

(1) the aggregate principal amount of Notes and other Senior Debt then outstanding, less

(2) the maximum amount of Senior Debt that can be incurred such that it is capable of being amortized to a zero balance through the termination date of the last to terminate of the Qualifying LNG SPAs then in effect (including any new Qualifying LNG SPAs entered into to replace an LNG SPA whose termination triggered the Indenture LNG SPA Prepayment Event) and produces a Projected Fixed DSCR of at least 1.40:1.00 through the terms of such Qualifying LNG SPAs, with such calculation using all such Qualifying LNG SPAs in respect of which there is in effect their Required Export Authorizations which are not Impaired, and using an interest rate equal to the weighted average interest rate of all Senior Debt (other than Working Capital Debt) then outstanding.

(f) The offer price in any LNG SPA Mandatory Offer will be equal to 100% of the principal amount of the Notes, plus accrued but unpaid interest, if any, to but excluding the date of purchase and will be payable in cash.

(g) In the event that the principal amount of Notes tendered pursuant to the LNG SPA Mandatory Offer, together with accrued but unpaid interest thereon to, but excluding, the date of purchase, is:

(1) in the case of an LNG SPA Mandatory Offer made pursuant to Section 4.21(c) less than the pro rata portion of the LNG SPA Mandatory Prepayment Amount (CTA Calculation) that is required to be applied toward the LNG SPA Mandatory Offer pursuant to the pro rata payment of Senior Debt Obligation provisions of the CSAA, the amount of the difference shall be applied as if it was a Senior Debt Obligation (other than Notes) to be prepaid in accordance with the LNG SPA Mandatory Prepayment provisions of the Common Terms Agreement;

(2) in the case of an LNG SPA Mandatory Offer made pursuant to Section 4.21(d) less than the pro rata portion of the LNG SPA Mandatory Prepayment Amount (CTA/Indenture Calculation) that is required to be applied toward the LNG SPA Mandatory Offer pursuant to the pro rata payment of Senior Debt Obligation provisions of the CSAA, the amount of the difference shall be applied as if it was a Senior Debt Obligation (other than Notes) to be prepaid in accordance with the LNG SPA Mandatory Prepayment provisions of the Common Terms Agreement; and

 

95


(3) in the case of an LNG SPA Mandatory Offer made pursuant to the Section 4.21(e), less than the LNG SPA Mandatory Offer Amount, the Company shall not have any further obligations with respect to such LNG SPA Mandatory Offer.

(h) The Company will comply with the requirements of Rule 14e-1 under the Exchange Act and any other securities laws and regulations thereunder to the extent such laws and regulations are applicable in connection with each repurchase of Notes pursuant to a LNG SPA Mandatory Offer. To the extent that the provisions of any securities laws or regulations conflict with the provisions of Section 3.09 or this Section 4.21 or compliance with the provisions of Section 3.09 or this Section 4.21 would constitute a violation of any such laws or regulations, the Company will comply with the applicable securities laws and regulations and will not be deemed to have breached its obligations under Section 3.09 or this Section 4.21 by virtue of such compliance.

Section 4.22 Access.

Each of the Company and TCP will, and will cause its respective Restricted Subsidiaries to, grant the Trustee or its designee from time to time, including during the pendency of an Unmatured Event of Default or an Event of Default, upon 15 days’ advance notice but no more than twice per calendar year (unless an Unmatured Event of Default or an Event of Default has occurred and is Continuing, in which case such access shall be granted upon reasonable prior written notice) reasonable access to all of its books and records and the physical facilities of the Development. All such inspections must be conducted during normal business hours, subject to the confidentiality arrangements pursuant to the confidentiality provisions of the CSAA, in a manner that does not disrupt the operation of the Development; provided, that the Company may redact pricing terms, sensitive technical information and/or other sensitive commercial information in any LNG SPAs, construction contracts or Material Project Agreements from the versions of such agreements made available to the Trustee or its designee. So long as an Unmatured Event of Default or an Event of Default has occurred and is Continuing, the reasonable fees and documented expenses of such persons will be for the account of the Obligors.

Section 4.23 Insurance.

Each of the Company and TCP will, and will cause its respective Restricted Subsidiaries to, obtain and maintain insurance with financially sound insurers, in such form and amounts as necessary to insure the probable maximum loss for the Development, except where not available on commercially reasonable terms and for certain exceptions that are consistent with the requirements of the Common Terms Agreement. The Company shall cause each insurance policy to name the Secured Parties and/or the Collateral Agent on behalf of the Secured Parties as named insureds, and in the case of any property insurance, loss payees to the extent provided under, in accordance with and pursuant to terms of, the CSAA.

For so long as the Loans or Senior Debt Commitments in connection therewith are outstanding, the maintenance of insurance required to be procured and maintained pursuant to the insurance covenant of the Common Terms Agreement shall be deemed to meet the insurance covenant in this Section 4.23.

 

96


Section 4.24 Compliance with Law.

Each of the Company and TCP will, and will cause its respective Restricted Subsidiaries to, comply in all respects with all applicable laws, rules, regulations and orders (excluding tax laws, in respect of which Section 4.05 is applicable), except where such failure to comply would not reasonably be expected to have a Material Adverse Effect.

Section 4.25 Limitation on Guarantees.

Each of the Company and TCP will not and will not permit any of its respective Restricted Subsidiaries to guarantee the obligations of others, except for:

(a) guarantees expressly contemplated by a Finance Document to which the Trustee is a party;

(b) guarantees incurred in the ordinary course of business pursuant to a Material Project Agreement or other ordinary course agreements of the Company and/or TCP;

(c) guarantees of the obligations of one or more of the Company, TCP or any of their respective Restricted Subsidiaries that are Indebtedness permitted under Section 4.08 hereof; and

(d) guarantees of the obligations (other than debt obligations for borrowed money) of third parties in an aggregate amount not exceeding $300,000,000.

Section 4.26 Material Project Agreements.

Each of the Company and TCP will and will cause each of its respective Restricted Subsidiaries, as applicable, to (i) maintain in effect all Material Project Agreements to which it is a party and (ii) comply in all material respects with its payment and other material obligations under the Material Project Agreements, except in each case:

(a) to the extent a Material Project Agreement is permitted to expire, be terminated or replaced under this Indenture or expires or is replaced in accordance with its terms;

(b) to the extent provided in Section 4.21 and Section 4.29 in relation to LNG SPAs; or

(c) to the extent that failure to do so would not reasonably be expected to have a Material Adverse Effect.

Each of the Company and TCP will not and will not permit any of its respective Restricted Subsidiaries to agree to any material amendment of any Material Project Agreement to which it is or becomes a party (except as permitted in Section 4.30) unless (a) a copy of such amendment has been delivered to the Trustee at least five days in advance of the effective date thereof along with a certificate of an Authorized Officer of the Company certifying that the proposed amendment or termination would not reasonably be expected to have a Material Adverse Effect; or (b) the Company, TCP or the applicable Restricted Subsidiary has obtained the consent of the Intercreditor Agent, if at least $1 billion of Loans or Senior Debt Commitments in connection therewith are outstanding, and if not, a majority of the Holders to such amendment.

 

97


Section 4.27 Customary Lifting and Balancing Arrangements.

Each of the Company and TCP and/or any of its respective Restricted Subsidiaries may enter into one or more lifting and balancing arrangements with an External LNG/CCS Entity containing provisions for borrowing, loaning or supply of Gas and/or LNG provided that:

(a) such lifting and balancing arrangements are entered into on fair and commercially reasonable terms that are not less favorable in the aggregate to the Company, TCP and/or the applicable Restricted Subsidiary than would be obtained in a comparable agreement with independent parties acting at arm’s length;

(b) the Company shall have delivered to the Trustee a certificate from an Authorized Officer of the Company certifying that (i) after giving effect to such lifting and balancing arrangements (and any amendment thereto), the Company, TCP and their Restricted Subsidiaries reasonably expect to be able to meet their performance and operational obligations under all then effective Material Project Agreements; (ii) no Material Adverse Effect would reasonably be expected to occur as a result of the implementation of the proposed lifting and balancing arrangement; and (iii) all conditions provided under this Section 4.27 have been satisfied; and

(c) each of the Company and TCP takes any action that may then be required to grant and perfect security over its rights, title and interest therein to the Senior Creditors as required by the CSAA.

Any such agreements shall be automatically deemed to be Material Project Agreements when the conditions above are satisfied.

Section 4.28 Sharing of Project Facilities.

Each of the Company, TCP and/or any of its respective Restricted Subsidiaries may enter into one or more agreements for the (x) sharing, quiet enjoyment and use by any External LNG/CCS Entity of any Project Facilities, and of any capacity, and/or processing or storage rights of any of the foregoing and/or (y) for the sharing, quiet enjoyment, and use by the Company, TCP and/or any of their Restricted Subsidiaries of facilities of an External LNG/CCS Entity, and of any capacity and/or processing or storage rights of any of the foregoing (each a “Sharing Arrangement”), in each case (whether on a capacity borrowing, lending or swap basis, a committed tolling or pooling basis or otherwise), subject only to the following conditions:

(a)

(1) the Sharing Arrangement does not involve any sale, lease or creation of a Lien over the assets of the Development, other than:

(A) any sale, lease or Lien over Real Estate which (i) is owned by the Company, TCP or a Restricted Subsidiary but is not reasonably necessary for siting, constructing or operating the Project Facilities (as then under construction and/or operation), (ii) would not otherwise materially adversely impact the construction and/or operation of the Project Facilities (as then under construction and/or operation) or their performance as contemplated under their applicable engineering, construction or procurement contract or (iii) could not reasonably be expected to have a Material Adverse Effect (with reasonable concurrence of the Independent Engineer in the case of reliance on clauses (i) or (ii)); and

 

98


(B) any Permitted Liens or any customary easements, related subordination and non-attornment provisions or similar Liens employed for the grant of quiet enjoyment rights of use over facilities whose use is shared by one or more entities and which could not reasonably be expected to have a Material Adverse Effect;

(2) Calcasieu Pass Operations, LLC or TransCameron Operations, LLC, as applicable, remains the operator of any applicable Project Facilities subject to such Sharing Arrangement;

(3) such Sharing Arrangement provides that, as a condition precedent to the commencement of any use, sharing or pooling of capacity in a facility that is owned by an External LNG/CCS Entity, that (A) such facility has reached substantial completion in accordance with the applicable engineering, construction and procurement contract or (B) such use, sharing or pooling of capacity relates solely to (1) access and/or easement rights to the site during development and/or construction activities associated with such facility or (2) sharing of facilities for testing and commissioning purposes prior to substantial completion in accordance with the applicable engineering, construction and procurement contract of such facility;

(4) the Company shall have delivered to the Trustee a certificate from an Authorized Officer of the Company (to which the Independent Engineer has reasonably concurred) certifying that after giving effect to such proposed Sharing Arrangement, the Company and TCP will hold capacity and use rights across the Project Facilities (as supplemented by any facilities developed and used by the External LNG/CCS Entity) sufficient for the Company and TCP to meet their obligations under all then-effective Material Project Agreements;

(5) each of the Company and TCP shall take all actions required to grant a perfected security interest over its rights, title and interest in the agreements evidencing such Sharing Arrangements to the Senior Creditors as required by the CSAA (or any other Security Document executed pursuant thereto);

(6) no Event of Default or Unmatured Event of Default has occurred and is continuing or would occur as a result of the implementation of the Sharing Arrangement, and the Company so certifies; and

 

99


(7) the Company shall have delivered to the Trustee a certificate from an Authorized Officer of the Company certifying that (A) all requirements described in this Section 4.28 have been complied with, (B) no Material Adverse Effect could reasonably be expected to arise as a result of implementing the proposed Sharing Arrangements and (A) all material Permits from a Governmental Authority required in respect of the implementation of such proposed Sharing Arrangement have been obtained or the Company shall have delivered to the Trustee a certificate from an Authorized Officer of the Company certifying that it reasonably expects such material consents can be obtained by the Obligors when necessary without material expense or delay to implementation of the Sharing Arrangement; and

(b) the amount of all Senior Debt (excluding Working Capital Debt and excluding all Indebtedness under Permitted Senior Debt Hedging Instruments) outstanding after giving effect to such Sharing Arrangements is capable of being amortized to a zero balance by the termination date of the last to terminate of the Qualifying Indenture LNG SPAs then in effect and produces a Projected Fixed DSCR that is not less than the Projected Fixed DSCR derived from amortizing the amount of all Senior Debt (excluding Working Capital Debt and excluding all Indebtedness under Permitted Senior Debt Hedging Instruments) outstanding prior to giving effect to such Sharing Arrangements to a zero balance by the termination date of the last to terminate of such Qualifying Indenture LNG SPAs, in each case, through the terms of such Qualifying Indenture LNG SPAs, with such calculations using such Qualifying Indenture LNG SPAs and using an interest rate equal to (i) in the case of an amortization calculation after giving effect to such Sharing Arrangements, the weighted average interest rate of all such Senior Debt (excluding Working Capital Debt) outstanding after giving effect thereto and (ii) in the case of an amortization calculation prior to giving effect to such Sharing Arrangements, the weighted average interest rate of all such Senior Debt (excluding Working Capital Debt) outstanding prior to giving effect thereto.

Any such agreements shall be automatically deemed to be Material Project Agreements when the conditions above are satisfied.

Section 4.29 LNG SPA Maintenance.

The Company will make a mandatory offer to repurchase Notes in accordance with Section 4.21 if the Company fails to maintain Qualifying LNG SPAs providing for commitments to purchase LNG in quantities at least equal to the Base Committed Quantity unless, upon termination of any Qualifying LNG SPA, the Company enters into Qualifying Indenture LNG SPA(s) (each, a “Replacement Indenture Qualifying LNG SPA”) within 90 days following such termination to the extent necessary to meet the Base Committed Quantity, which period will be automatically extended by an additional 90 days if the Company certifies to the Trustee prior to the termination of the initial 90 day period that:

(a) the Company intends to replace such terminated LNG SPA with one or more LNG SPAs that would be Qualifying LNG SPAs that enable the Company to meet the Base Committed Quantity requirement set forth above and is diligently pursuing such replacement; and

(b) the termination of such Qualifying LNG SPA would not reasonably be expected to result in a Material Adverse Effect during such subsequent cure period;

 

100


provided that (i) if any Loans or Senior Debt Commitments in connection therewith are outstanding and the Intercreditor Agent has approved an extension of any of the above cure periods, then the Company shall have the benefit of such extended cure period under this Indenture to replace such terminated LNG SPA and (ii) if no Loans or Senior Debt Commitments in connection therewith are outstanding, the period within which to replace such terminated LNG SPA will be 360 days.

A “Qualifying LNG SPA” comprises each of (i) the Initial LNG SPAs (other than the Excess Capacity LNG SPA), (ii) any LNG SPA entered into for a Qualifying Term in accordance with Section 4.31 and (iii) any other LNG SPA that meets each of the following conditions:

(a) With respect to any new LNG SPA or a Replacement Indenture Qualifying LNG SPA:

(1) for so long as at least $1 billion of Loans or Senior Debt Commitments in connection therewith are outstanding, such LNG SPA is approved by the Intercreditor Agent;

(2) such LNG SPA is entered into for a Qualifying Term and is entered into (A) with an Investment Grade LNG Buyer (or guaranteed by an Investment Grade entity), (B) with a counterparty that is party to one of the Initial LNG SPAs (other than the Excess Capacity LNG SPA), (C) in the case of any LNG SPA that is a replacement of an LNG SPA referenced in clauses (a) or (d) of the definition of “Initial LNG SPAs,” an entity with consolidated net tangible assets of at least $15 billion (or guaranteed by an entity with such consolidated net tangible assets), (D) in the case of any LNG SPA entered into in accordance with the provisions described below under Section 4.31 or any LNG SPA that is a replacement of an LNG SPA referenced in clauses (b), (c), (e) or (f) of the definition of “Initial LNG SPAs,” so long as the Company has other Qualifying LNG SPAs for at least 6.0 MTPA of ACQ with counterparties that are an Investment Grade LNG Buyer (or guaranteed by an Investment Grade entity), an entity with consolidated net tangible assets of at least $3 billion per 1.0 MTPA of ACQ (or guaranteed by an entity with such consolidated net tangible assets), or (E) for so long as at least $1 billion of Loans or Senior Debt Commitments in connection therewith are outstanding, any entity approved pursuant to the terms of the Loans; or

(3) in the case of:

(A) any new LNG SPA, the Company has obtained and delivered to the Trustee a Rating Reaffirmation which takes into account the proposed LNG SPA and LNG Buyer; or

(B) one or more Replacement Indenture Qualifying LNG SPAs that replace one or more terminated LNG SPAs which, in the aggregate, would require the delivery of an ACQ of no more than 4.0 MTPA in order to replace such terminated LNG SPAs in full, the Company has obtained and delivered to the Trustee a Rating Reaffirmation which (y) takes into account the Replacement Indenture Qualifying LNG SPAs and the LNG Buyers and (z) reaffirms the Company’s rating in effect immediately prior to the occurrence of the termination event giving rise to the termination of the LNG SPAs being replaced (but prior to the running of any applicable notice period or cure period thereunder); and

 

101


(b) no Material Adverse Effect occurs, or could reasonably be expected to occur, as a result of entering into such LNG SPA or, in the case of a Replacement Indenture Qualifying LNG SPA, the termination of the LNG SPA being replaced and the entering into of the Replacement Indenture Qualifying LNG SPA, taken as a whole.

The Company will notify the Trustee upon entry into any new Qualifying LNG SPA promptly (and in any event, within 30 days of entry into such agreement), which notice will provide (a) a description thereof to the Trustee consistent with the description of the Initial LNG SPAs in the Offering Memorandum, (b) a statement of whether the Non-FTA Authorization, FTA Authorization, both of the foregoing or any other Export Authorization(s) are Required Export Authorizations in respect of such Qualifying LNG SPA, in accordance with the definition of Required Export Authorization, together with reasonable background information to support such designation and (c) a certification to the effect set forth in clause (b) above. Any LNG SPA that becomes a Qualifying LNG SPA will automatically be deemed to be a Material Project Agreement.

Section 4.30 Amendment of LNG SPAs.

Except to the extent such amendment or modification is required by applicable law or regulation of any Governmental Authority, the Company will not agree to any amendment or modification to the terms or provisions of any Qualifying LNG SPA if such amendment or modification would or could reasonably be expected to have a Material Adverse Effect.

Section 4.31 Sale of Supplemental Quantities.

LNG SPAs may be entered into by the Company in respect of all or any portion of the Supplemental Quantity of LNG and such LNG SPAs may be of any duration, on any terms and to buyers of any credit quality; provided that (a) performance under such LNG SPAs would not reasonably be expected to have a Material Adverse Effect; and (b) entry into and the terms of such LNG SPA will not result in a breach of any Required LNG SPA then in effect.

Section 4.32 Sale of Pre-Commercial Quantities.

The Company shall be permitted to enter into LNG SPAs in respect of any LNG produced or to be produced by the LNG Facility prior to the Commercial Operation Date, which LNG SPAs may be of any duration, on any terms and to buyers of any credit quality; provided that, (a) the Required LNG SPAs are then in full force and effect; (b) any obligations in such LNG SPA with respect to the period occurring after the Commercial Operation Date satisfy Section 4.31; (c) the performance by the Company of its obligations under such LNG SPAs could not reasonably be expected to have a material adverse effect on the ability of the Company to perform its obligations under the Required LNG SPAs; and (d) the entry into and the terms of such LNG SPA shall not result in a breach or default of any Required LNG SPA then in effect or the Impairment of any then-required material Permit.

 

102


Section 4.33 Export Authorizations

The Company will use commercially reasonable efforts to maintain in full force and effect both the FTA Authorization and the Non-FTA Authorization, and shall comply therewith, except where failure to do so would not reasonably be expected to have a Material Adverse Effect.

Section 4.34 FERC Order.

Each of the Company and TCP will maintain in full force and effect and comply in all material respects with the FERC Order, except where failure to do so would not reasonably be expected to have a Material Adverse Effect.

The Company and TCP may amend or modify the FERC Order and any conditions thereof only to the extent that such amendment or modification would not reasonably be expected to have a Material Adverse Effect.

Section 4.35 Hedging Arrangements.

Each of the Company and TCP will not and will not permit any of its respective Restricted Subsidiaries to enter into Hedging Instruments other than Permitted Hedging Instruments.

Section 4.36 Project Construction; Maintenance of Properties.

Each of the Company and TCP will, and will cause its respective Restricted Subsidiaries to, use their respective commercially reasonable efforts to perform, or cause to be performed, all work and services required or appropriate in connection with the design, engineering, construction, testing and commencement of operations of the Development. On or prior to the Project Completion Date, the Trustee shall have received a certificate of the Independent Engineer confirming (a) that Facility Substantial Completion has occurred pursuant to the EPC Contract (subject to the completion of any punch list items thereunder), (b) that the applicable performance tests under each of the Material Construction Contracts have been successfully passed in accordance with such Material Construction Contract, (c) that the Project Facilities are Operational and (d) the Company’s calculation of the Permitted Completion Costs and that the Company has reserved an amount sufficient for the Permitted Completion Costs.

Section 4.37 Maintenance of Liens.

(a) Each of the Company and TCP will, and will cause its respective Restricted Subsidiaries to, grant a security interest to the Collateral Agent in its right, title and interest in, to and under its property to the extent and in accordance with, and subject to the exclusions set forth in, the Security Documents and each of the Company and TCP will, and will cause its respective Restricted Subsidiaries to, take, or cause to be taken, all action reasonably required by the Collateral Agent to maintain and preserve the Security Interests created by the Security Documents to which it is a party and the priority of such Security Interests as set forth in such Security Documents.

(b) Each of the Company and TCP will, and will cause its respective Restricted Subsidiaries to, from time to time execute or cause to be executed any and all further instruments (including financing statements, continuation statements and similar statements with respect to any Security Document) reasonably requested by the Collateral Agent for such purposes.

 

103


(c) Each of the Company and TCP will, and will cause its respective Restricted Subsidiaries to, preserve and maintain good, legal and valid title to, or rights in, the Collateral free and clear of Liens other than Permitted Liens to the extent and in accordance with, and subject to the exclusions set forth in, the Security Documents. Each of the Company and TCP will, and will cause its respective Restricted Subsidiaries to, promptly discharge at the Obligors’ cost and expense, any Lien (other than Permitted Liens) on the Collateral to the extent and in accordance with, and subject to the exclusions set forth in, the Security Documents.

Section 4.38 Credit Rating Agencies.

The Company will use its commercially reasonable efforts to cause each series of the Notes to be rated by at least two Recognized Credit Rating Agencies. If any Recognized Credit Rating Agency ceases to be a “nationally recognized statistical rating organization” registered with the SEC or ceases to be in the business of rating securities of the type and nature of the Notes, the Company may replace the rating received from it with a rating from any other Recognized Credit Rating Agency.

Section 4.39 Additional Note Guarantees.

If the Company, TCP or any of their respective Restricted Subsidiaries acquires or creates another Domestic Subsidiary, then such Domestic Subsidiary will (a) execute a supplemental indenture in the form attached hereto as Exhibit E (together with a corresponding Notation of Guarantee in the form attached hereto as Exhibit D), (b) accede to the CSAA and become a “Guarantor” and “Obligor” thereunder, and in each case within 15 Business Days of the date on which such Domestic Subsidiary is acquired or created and (c) if applicable, execute the Common Terms Agreement and any Facility Agreement as a guarantor and “Obligor” thereunder; provided that any such Restricted Subsidiary that is an Immaterial Subsidiary is not required to become a Guarantor until it ceases to be an Immaterial Subsidiary. The Company shall deliver an Opinion of Counsel to the Trustee as of the date of such accession to the CSAA and execution of the supplemental indenture stating that such supplemental indenture and accession to the CSAA are legal, valid and binding obligations of such Domestic Subsidiary enforceable against it in accordance with their respective terms.

Section 4.40 Designation of Restricted and Unrestricted Subsidiaries.

The Board of Directors (or equivalent governing body) of the Company may designate any Restricted Subsidiary of the Company to be an Unrestricted Subsidiary, and the Board of Directors (or equivalent governing body) of TCP may designate any Restricted Subsidiary of TCP to be an Unrestricted Subsidiary, in each case, if that designation would otherwise comply with the provisions of this Section 4.40. If a Restricted Subsidiary is designated as an Unrestricted Subsidiary, the aggregate Fair Market Value of all outstanding Investments owned by the Company, TCP and their Restricted Subsidiaries in the Subsidiary designated as an Unrestricted Subsidiary will be deemed to be an Investment made as of the time of the designation and will reduce the amount available under one or more clauses of the definition of Permitted Investments, as determined by the Company. That designation will only be permitted if the Investment would be permitted at that time and if the Restricted Subsidiary otherwise meets the definition of an Unrestricted Subsidiary.

 

104


Any designation of a Subsidiary of the Company or TCP as an Unrestricted Subsidiary will be evidenced to the Trustee by filing with the Trustee a certified copy of a resolution of the Board of Directors (or equivalent governing body) of the Company or TCP, as applicable, giving effect to such designation and a certificate from an Authorized Officer certifying that such designation complied with the preceding conditions. If, at any time, any Unrestricted Subsidiary would fail to meet the preceding requirements as an Unrestricted Subsidiary, it will thereafter cease to be an Unrestricted Subsidiary for purposes of this Indenture and any Indebtedness of such Subsidiary will be deemed to be incurred by a Restricted Subsidiary as of such date and, if such Indebtedness is not permitted to be incurred as of such date by Section 4.08, the Company will be in default of the covenants described in such section. The Board of Directors (or equivalent governing body) of the Company or TCP, as applicable, may at any time designate any Unrestricted Subsidiary to be a Restricted Subsidiary. Any such designation will be deemed to be an incurrence of Indebtedness by a Restricted Subsidiary of any outstanding Indebtedness of such Unrestricted Subsidiary, and such designation will only be permitted if (a) such Indebtedness is permitted by Section 4.08 calculated on a pro forma basis; and (b) no Event of Default or Unmatured Event of Default would be in existence following such designation.

Section 4.41 Separateness.

The Company and its Subsidiaries, as a consolidated group, and TCP and its Subsidiaries, as a consolidated group, shall each at all times:

(a) observe all applicable entity procedures necessary to maintain its separate existence and formalities, including:

(i) maintain minutes or records of meetings of the members and/or managers of the Company and its Subsidiaries and TCP and its Subsidiaries;

(ii) act on behalf of itself only pursuant to due authorization of the members and/or managers, including, when applicable, any independent managers or members; and

(iii) conduct its own business in its own name and through authorized agents pursuant to its Constitutional Documents;

(b) allocate fairly and reasonably any shared expenses, including overhead for shared office space or common employees (if any);

(c) use separate stationery, invoices and checks bearing its own name;

(d) prepare and maintain its own full and complete books, accounting records (including books of account and payroll, if any) and other documents and records, in each case which are separate and apart from the books, accounting records and other documents and records of the Sponsor or any Affiliate thereof;

 

105


(e) maintain separate bank accounts in its own name or otherwise pursuant to the Finance Documents and make all investments by or on behalf of the Company and its Subsidiaries and TCP and its Subsidiaries solely in its name except as otherwise provided by the Finance Documents;

(f) separate its property and not allow funds or other assets to be commingled with the funds and other assets of, held by, or registered in the name of the Sponsor or any Affiliate thereof, and maintain its assets in such a manner that it is not costly or difficult to identify or ascertain such assets, all except to the extent otherwise provided by the Finance Documents;

(g) not hold itself out as being liable for the debts of the Sponsor or any Affiliate thereof and not guarantee the debts of the Sponsor or any Affiliate thereof except as permitted by the Finance Documents;

(h) not acquire or assume obligations or securities of, or make loans or advances to, any of its Affiliates except as required under the Finance Documents;

(i) maintain separate financial statements, showing its assets and liabilities separate and apart from those of any other Person, and not have its assets listed on the balance sheet of any other Person; provided that such Obligor may also report its financial statements on a consolidated or combined basis with one or more of its Affiliates in accordance with GAAP so long as appropriate notation is made on such consolidated financial statements to indicate the separateness of the Company and its Subsidiaries and TCP and its Subsidiaries from such Affiliate(s) and to disclose the separate nature of the Company and its Subsidiaries; and TCP and its Subsidiaries indebtedness;

(j) prepare and file its own tax returns separate from those of any Person except to the extent that the Company and its Subsidiaries and TCP and its Subsidiaries are treated as a “disregarded entity” for tax purposes and are not required to file tax returns under applicable law;

(k) pay its own liabilities and expenses out of its own assets (except as provided under the Finance Documents);

(l) pay the salaries of its own employees, if any, and maintain a sufficient number of employees in light of its contemplated business operations (either directly or through contractual arrangements to provide such services that such employees would provide) and not permit its employees, if any, to participate in or receive payroll benefits or pension plans of or from any of its Affiliates;

(m) maintain adequate capitalization in light of its contemplated business and obligations;

(n) hold itself out to third parties as a legal entity, separate and distinct and independent from any other entity, conduct its own business solely under its name and correct any known misunderstanding as to the separateness of the Obligors from any other Person;

 

106


(o) procure that each of the Company and TCP shall have an independent director or manager; and

(p) have and maintain Constitutional Documents which comply with the requirements of this Section 4.41;

provided that no limitation in this Section shall apply to the Company and its Subsidiaries as among one another or TCP and its Subsidiaries as among one another.

Section 4.42 Use of Proceeds.

The Company will use the proceeds of the Notes solely for purposes permitted in the applicable Finance Documents.

Section 4.43 Payments for Consents.

Each of the Company and TCP will not, and will not permit its respective Restricted Subsidiaries to, directly or indirectly, pay or cause to be paid any consideration to or for the benefit of any Holder, in its capacity as a Holder, for or as an inducement to any consent, waiver or amendment of any of the terms or provisions of this Indenture or the Notes unless such consideration is offered to be paid and is paid to all Holders that consent, waive or agree to amend in the time frame set forth in the solicitation documents relating to such consent, waiver or agreement.

Section 4.44 Application of Covenants to TCP and its Subsidiaries Following a Permitted Pipeline Sale.

From and after the consummation of a Permitted Pipeline Sale, none of the covenants or prepayment provisions (except as set forth in the second paragraph in Section 4.12(a)) shall be applicable to TCP or any of its Subsidiaries. If a Permitted Pipeline Sale has occurred, the aggregate Fair Market Value of all outstanding Investments owned by the Company and its Restricted Subsidiaries in TCP or any of its Subsidiaries will be deemed to be an Investment made as of the time of the Permitted Pipeline Sale and will reduce the amount available under one or more clauses of the definition of Permitted Investments, as determined by the Company; provided that, such Permitted Pipeline Sale will only be permitted if each such Investment in TCP or any of its Subsidiaries would be permitted at that time as a Permitted Investment (other than under clause (e), (f), (k), (q), (r) or (s) of the definition thereof).

Section 4.45 Changes in Covenants when Notes Rated Investment Grade.

 

  (a)

If, on any date following the Notes Issue Date:

(1) each series of the Notes becomes Investment Grade; and

 

107


(2) no Unmatured Event of Default or Event of Default shall have occurred and be Continuing, then, beginning on that day and continuing at all times thereafter regardless of any subsequent changes in the rating of the Notes, the covenants set forth in Section 5.01(c), Section 4.18 and Section 4.35 will no longer be applicable to the Notes.

(b) In addition, if, on any date following the date on which (1) the Company satisfies the conditions in clauses (1) and (2) of clause (a) above, then Section 4.13 will no longer be applicable to the Notes, beginning on such date and continuing until the Reversion Date (as defined below).

(c) If, on any date, either series of the Notes cease to be Investment Grade, then on such date (the “Reversion Date”) Section 4.13 will be reinstated as if such section had never been suspended and will be applicable unless and until the conditions in clauses(1) and (2) of clause (a) above are satisfied. No Unmatured Event of Default, Event of Default or breach of any kind shall be deemed to exist under this Indenture or any series of Notes with respect to Section 4.13 and neither the Company nor any of its Subsidiaries shall bear any liability for any actions taken or events occurring during the Suspension Period (as defined below), or any actions taken at any time pursuant to any contractual obligation arising prior to the Reversion Date, regardless of whether such actions or events would have been permitted if Section 4.13 remained in effect during such period. The period of time between the date of the suspension of Section 4.13 and the Reversion Date is referred to as the “Suspension Period.”

(d) In addition, on any date following the date on which the Company satisfies the conditions in clauses (1) and (2) of clause (a) above, the restrictions contained in the covenants set forth in Section 4.08 and Section 4.25 shall be of no further force and effect and shall be replaced with the following:

“Each of the Company and TCP will not and will not permit any of its respective Restricted Subsidiaries to incur Indebtedness or to issue preferred stock; provided that the Company and TCP and/or any of their Restricted Subsidiaries may incur Indebtedness and may issue preferred stock (i) permitted to be incurred and/or issued as described in paragraphs (a) through (q) of Section 4.08 (for the avoidance of doubt, including any Additional Senior Debt incurred in accordance with the provisions described under Section 4.09) and (ii) if either of the following conditions has been satisfied:

 

  (A)

The Company shall have delivered to the Trustee a certificate from an Authorized Officer of the Company certifying that the amount of all Senior Debt (excluding Working Capital Debt and excluding all Indebtedness under Permitted Senior Debt Hedging Instruments) outstanding, after giving effect to the incurrence of such Indebtedness, is capable of being amortized to a zero balance by the termination date of the last to terminate of the Qualifying Indenture LNG SPAs then in effect and produces a Projected Fixed DSCR of at least 1.40:1.00 through the terms of such Qualifying Indenture LNG SPAs (with such ratio calculated using such Qualifying Indenture LNG SPAs, and using an interest rate equal to the weighted average interest rate of Senior Debt (excluding Working Capital Debt) outstanding after giving effect to the incurrence of such Indebtedness and the application of the proceeds therefrom); or

 

108


  (B)

The Company has obtained and delivered to the Trustee a Rating Reaffirmation in respect of the Notes after giving effect to the incurrence of such Indebtedness.”

ARTICLE 5

SUCCESSORS

Section 5.01 Merger, Liquidation, Sale of All Assets.

The Company will not dissolve or liquidate nor consolidate with or merge with or into another Person (regardless of whether the Company is the surviving entity), convert into another form of entity or continue in another jurisdiction, or sell, assign, transfer, lease, convey or otherwise dispose of all or substantially all of the properties or assets of the Company and its Restricted Subsidiaries taken as a whole, in one or more related transactions, to another Person, unless:

(a) either (i) the Company is the surviving entity or (ii) the Person formed by or surviving such consolidation, merger, conversion or continuation (if other than the Company) or to which such sale, assignment, transfer, lease, conveyance or disposition is made is a corporation, limited liability company or partnership organized or existing under the laws of the United States, any state of the United States or the District of Columbia and assumes the Company’s obligations under the Notes, this Indenture and the Security Documents pursuant to a supplemental indenture or appropriate modifications (if necessary) to the Security Documents;

(b) no Event of Default or Unmatured Event of Default would exist immediately after giving effect to such transaction or series of related transactions;

(c) the amount of all Senior Debt (excluding Working Capital Debt and excluding all Indebtedness under Permitted Senior Debt Hedging Instruments) outstanding after giving effect thereto, is capable of being amortized to a zero balance by the termination date of the last to terminate of the Qualifying LNG SPAs then in effect and produces a Projected Fixed DSCR that is not less than the lower of (i) 1.40:1.00 and (ii) the Projected Fixed DSCR derived from amortizing the amount of all Senior Debt (excluding Working Capital Debt and excluding all Indebtedness under Permitted Senior Debt Hedging Instruments) outstanding prior to giving effect thereto to a zero balance by the termination date of the last to terminate of such Qualifying LNG SPAs, in each case through the terms of such Qualifying LNG SPAs, with such calculations using such Qualifying LNG SPAs and using an interest rate equal to (i) in the case of an amortization calculation after giving effect to such consolidation or merger or sale, assignment, transfer, lease, conveyance or disposition, the weighted average interest rate of all such Senior Debt (excluding Working Capital Debt) outstanding after giving effect thereto and (ii) in the case of an amortization calculation prior to giving effect to such consolidation or merger or sale, assignment, transfer, lease, conveyance or disposition, the weighted average interest rate of all such Senior Debt (excluding Working Capital Debt) outstanding prior to giving effect thereto; and

(d) the Company shall have delivered to the Trustee a certificate from an Authorized Officer and an Opinion of Counsel, each stating that such consolidation or merger, conversion or continuation, or sale, assignment, transfer, lease, conveyance or disposition and such supplemental indenture and Security Documents, if any, comply with this Indenture and that all conditions precedent provided for in this Indenture relating to such transaction have been complied with.

 

109


Section 5.02 Successor Corporation Substituted.

Upon any consolidation or merger, conversion or continuation, or sale, assignment, transfer, lease, conveyance or disposition or any transfer of all or substantially all of the assets of the Company in a transaction that is subject to, and that complies with the provisions of, Section 5.01, the successor Person formed by such consolidation, conversion or continuation, or into which the Company merged or to which such sale, assignment, transfer, lease, conveyance or disposition is made will succeed to, and be substituted for (so that from and after the date of such consolidation or merger, conversion or continuation, or sale, assignment, transfer, lease, conveyance or disposition, the provisions of this Indenture referring to the “Company” shall refer instead to the successor Person and not to the Company), and may exercise every right and power of, the Company under this Indenture and the Notes with the same effect as if such successor Person had been named as the Company in this Indenture and the Notes and thereafter the predecessor Company will have no continuing obligations under the Indenture, the Notes and the Security Documents (and such change shall not in any way constitute or be deemed to constitute a novation, discharge, rescission, extinguishment or substitution of the existing Indebtedness and any Indebtedness so effected shall continue to be the same obligation and not a new obligation).

ARTICLE 6

DEFAULTS AND REMEDIES

Section 6.01 Events of Default.

The following events will be events of default under this Indenture (each, an “Event of Default”):

(a) Indenture Payment Default (an “Indenture Payment Default”):

(1) the Company fails to pay principal amounts due on the Notes; provided that if failure to pay occurs due to a purely administrative error, the Company shall have three Business Days to cure such failure; or

(2) the Company fails to pay interest or other amounts due on the Notes within thirty days of the same becoming due.

(b) Breach of Certain Covenants: except as specifically provided for in another Event of Default under this Section 6.01:

(1) breach by the Company, TCP or any Restricted Subsidiary of any covenant described in Section 5.01;

(2) failure by the Company to consummate a purchase of Notes when required pursuant to the provisions described under Section 4.12, Section 4.17, Section 4.19, Section 4.20 and Section 4.21;

 

110


(3) breach by the Company, TCP or any Restricted Subsidiary of any covenant described in Section 4.05, Section 4.08, Section 4.12 (to the extent not covered by the immediately preceding clause (2)), Section 4.14, Section 4.18, Section 4.24, Section 4.25 and Section 4.26; and in each case that is not corrected or cured within 30 days following the earlier of (A) any Obligor becoming aware of such failure; and (B) written notice from the Trustee or Holders of 3313% of the principal amount of Notes outstanding;

(4)

(A) breach by the Company, TCP or any Restricted Subsidiary of any covenant described in Section 4.13, Section 4.15, Section 4.33 and Section 4.36; or

(B) material breach by the Company, TCP or any Restricted Subsidiary of any of the other covenants in this Indenture or the Notes;

in the case of each of sub-clauses (A) and (B) of this clause (4), that is not corrected or cured within 90 days after the earlier of (i) any Obligor becoming aware of such breach and (ii) written notice from the Trustee or Holders of 3313% of the principal amount of Notes outstanding;

(5) any Permit required as described in Section 4.34 is Impaired and such Impairment could reasonably be expected to have a Material Adverse Effect unless such Impairment is cured no later than 90 days (or to the extent no Loans or Senior Debt Commitments in connection therewith are then outstanding, 360 days) following the occurrence thereof (or such longer period, if any, presented by any administrative, legal, regulatory or statutory time period applicable thereto; provided that if any Loans or Senior Debt Commitments in connection therewith are then outstanding, the Company shall have no more than 180 days in the aggregate to cure such Impairment); or

(6) material breach by the Pledgor of any covenant contained in the Pledge Agreement that is not corrected or cured within 30 days after the earlier of (A) the Pledgor or any Obligor becoming aware of such failure; and (B) written notice from the Trustee or Holders of 3313% of the principal amount of Notes outstanding.

(c) Bankruptcy:

(1) a Bankruptcy with respect to an Obligor or the Pledgor has occurred; or

(2) a Bankruptcy shall occur with respect to a Specified Counterparty, unless:

(A) the Company notifies the Collateral Agent and the Trustee that it intends to enter into a replacement contract with a new counterparty or guarantor, as applicable, or to amend or designate an existing contract in a manner that such existing contract shall thereafter satisfy the criteria to replace the contract with the Specified Counterparty that is in Bankruptcy;

(B) the Company diligently pursues such contract;

 

111


(C) such contract is entered within 360 days of the Bankruptcy of the Specified Counterparty;

(D) in the case of any Specified Counterparty that is a counterparty to a Required LNG SPA or a guarantor in respect of a Required LNG SPA, such contract meets the requirements of a Qualifying LNG SPA; and

(E) in the case of any Specified Counterparty that is a Construction Contractor or a guarantor party to a Parent Guarantee:

(i) such contract is on terms and conditions, taken as a whole, not materially likely to cause the Company to fail to meet the Project Completion Date by the Date Certain;

(ii) the new contractor or guarantor is a nationally or internationally recognized contractor; and

(iii) the Company has delivered to the Trustee a certificate of the Independent Engineer certifying that such counterparty is capable of completing the applicable portion of the Project Facilities; provided that this sub-clause (E) will not apply if the replacement contract or guarantee is reasonably acceptable to: (x) if the aggregate Loans then outstanding is greater than 25% of the total Senior Debt then outstanding, the Intercreditor Agent (acting on the instructions of the Requisite Secured Parties); or (y) if the aggregate secured bank debt then outstanding is less than 25% of the total Senior Debt then outstanding, Holders of greater than 50% in aggregate principal amount of the then outstanding Notes;

provided that, a Bankruptcy with respect to a counterparty to a PPS Gas Agreement or a guarantor in respect of a PPS Gas Agreement shall not result in an Indenture Event of Default if (I) such Specified Counterparty does not reject the applicable PPS Gas Agreement or guaranty in respect of such PPS Gas Agreement under the applicable Bankruptcy proceeding or (II) the Company obtains a Rating Reaffirmation which takes into account the bankruptcy of such Specified Counterparty.

(d) Abandonment: Abandonment of the Development has occurred and is continuing.

(e) Event of Taking: An Event of Taking that would reasonably be expected to have a Material Adverse Effect has occurred.

(f) Security Interests Invalid: Any of the Security Interests over a material portion of the Collateral ceases to be validly perfected in favor of the Collateral Agent on behalf of the Secured Parties.

 

112


(g) Unsatisfied Judgments: one or more final judgments for the payment of money in excess of $150,000,000 in the aggregate (net of insurance proceeds which are reasonably expected to be paid), in each case, against an Obligor or the Pledgor or against any other Person where an Obligor or the Pledgor is liable to satisfy such judgment, which judgment is by one or more Governmental Authorities, courts, arbitral tribunals or other bodies having jurisdiction over any such entity, and such judgment or judgments remain unpaid, unstayed on appeal, undischarged, unbonded or undismissed for a period of 90 days after the date of entry of such judgment; provided that such 90-day period will be stayed if an appeal in respect of such judgment or judgments has been filed and not dismissed.

(h) Unenforceability of this Indenture and Security Documents: This Indenture, the CSAA (including the guarantees in the CSAA provided by the Guarantors) or any other Security Document (other than (i) a Direct Agreement in respect of any LNG SPA that is not a Required LNG SPA then in full force and effect or (ii) any Direct Agreement in the case where the occurrence of this Event of Default has been triggered by an event affecting the underlying Material Project Agreement and a mandatory offer to purchase under Section 4.12, Section 4.17, Section 4.19, Section 4.20 and Section 4.21 or other Event of Default is applicable) is:

(1) declared unenforceable in a final judgment of a court of competent jurisdiction against any party (other than the Trustee or Holders or any Senior Creditors);

(2) expressly repudiated in writing by any party thereto (other than the Trustee or Holders or any Senior Creditors); or

(3) shall have been terminated (other than pursuant to the terms thereof following discharge in full of all obligations thereof or otherwise by agreement in writing of the parties thereto not as a result of an Event of Default hereunder).

(i) Senior Debt Cross Payment Default/Cross-Acceleration Default:

(1) Failure by any Obligor to pay when due any principal payments due on any Senior Debt (other than the Notes) in a principal amount over $100,000,000 in the aggregate;

(2) failure by any Obligor to pay interest or other amounts on any Senior Debt (other than the Notes) in a principal amount over $100,000,000 within three Business Days of such interest or other amounts becoming due; or

(3) commencement of a Security Enforcement Action in accordance with the CSAA.

(j) Cross-Acceleration Default (other Indebtedness): A default with respect to any Indebtedness (other than any amount due in respect of Senior Debt Obligations and Subordinated Debt) of any Obligor in a principal amount over $100,000,000 in the aggregate, which default has continued beyond any applicable grace period, to the extent that it causes the entire amount of such Indebtedness to become due and such Indebtedness remains unpaid or the acceleration of its stated maturity unrescinded.

 

113


Section 6.02 Declaration of Declared Event of Default.

The Trustee will, if so directed by the Holders of at least 3313% of the principal amount of Notes of such series outstanding, or Holders of at least 3313% of the principal amount of Notes of such series outstanding may, declare, by notice in writing to the Company (which notice, if given by the Holders, may also be delivered by the Holders to the Trustee), the occurrence of an Event of Default (an “Declared Event of Default”) on and at any time after the occurrence of an Event of Default, unless Holders of Notes of such series holding a greater percentage of the principal amount of Notes of such series direct the Trustee otherwise). An Event of Default also will be deemed to have occurred and been declared without such declaration or other notice upon the occurrence of an Event of Default described in Section 6.01(c)(1).

The Trustee will deliver a copy of any notice declaring the occurrence of an Event of Default (whether initially delivered by the Trustee or Holders) to the Collateral Agent pursuant to the CSAA.

Section 6.03 Acceleration.

In the case of an Event of Default described in Section 6.01(c)(1), all Senior Debt Obligations under the Notes will accelerate automatically and will immediately become due and payable without presentment, demand, vote or other notice or action of any kind. Upon the occurrence and Continuation of any other Declared Event of Default, the Trustee or Holders of at least 3313% of the principal amount of Notes outstanding may declare all the Notes to be due and payable immediately, by notice in writing to the Company (which notice, if given by the Holders, shall also be delivered by the Holders to the Trustee), specifying the Event of Default. Upon any such declaration of acceleration, the Notes shall become due and payable immediately. Such notice may be included within a notice from the Trustee or the applicable Holders of the Notes declaring the occurrence of such Event of Default. The Trustee will deliver a copy of any notice of acceleration of the Senior Debt Obligations under the Notes (whether initially delivered by the Trustee or Holders) to the Collateral Agent pursuant to the CSAA.

Section 6.04 Waivers of Defaults and Acceleration.

Holders of more than 50% in aggregate principal amount of the then outstanding Notes of such series by notice to the Trustee may on behalf of the Holders of all of the Notes of such series waive a Continuing Unmatured Event of Default, Continuing Event of Default or Declared Event of Default, except a Continuing Unmatured Event of Default, Continuing Event of Default or Declared Event of Default in the payment of the principal of, premium, if any, or interest on, the Notes of such series (including in connection with an offer to purchase); provided, that the Holders of more than 50% in aggregate principal amount of the then outstanding Notes of such series may rescind an acceleration and its consequences, including any related payment default that resulted from such acceleration. Any notice delivered in respect of any such waiver or rescission shall be referred to as a “Cessation Notice.”

Upon any such waiver, such Unmatured Event of Default, Event of Default or Declared Event of Default shall cease to exist, and any Unmatured Event of Default, Event of Default or Declared Event of Default arising therefrom shall be deemed to have been cured for every purpose of this Indenture.

 

114


The Trustee will deliver a copy of any Cessation Notice received from Holders of more than 50% in aggregate principal amount of the then outstanding Holders of the Notes of such series to the Collateral Agent pursuant to the CSAA.

Section 6.05 Remedies of Holders.

If a Declared Event of Default occurs and is Continuing, the Trustee may pursue any available remedy to collect the payment of principal, premium, if any, and interest on the Notes or to enforce the performance of any provision of the Notes or this Indenture.

Except as set forth in Section 6.07 and Section 6.12, a Holder of a Note may pursue any remedy with respect to this Indenture or the Notes of such series only if:

(a) such Holder has previously given the Trustee written notice that an Event of Default is Continuing;

(b) Holders of at least 3313% of the principal amount of Notes of such series outstanding make a written request to the Trustee to pursue the remedy;

(c) such Holder or Holders have offered to the Trustee indemnity or security satisfactory to the Trustee against any loss, liability or expense;

(d) the Trustee has not complied with such request within 60 days after the receipt of the request and the offer of security or indemnity; and

(e) Holders of more than 50% in aggregate principal amount of the then outstanding Notes of such series have not given the Trustee a direction inconsistent with such request within such 60-day period.

Any notice of an Event of Default, notice of acceleration or instruction to the Trustee to provide a notice of an Event of Default, notice of acceleration or take any other action in connection with an Event of Default and/or acceleration of the Notes (a “Noteholder Direction”) provided by any one or more Holders (each a “Directing Holder”) must be accompanied by a written representation from each such noteholder of Notes delivered to the Company and the Trustee that such noteholder is not (or, in the case such noteholder is DTC, or its nominee, that such noteholder is being instructed solely by beneficial owners that have represented to such noteholder that they are not) Net Short (a “Position Representation”), which representation, in the case of a Noteholder Direction relating to the delivery of a notice of an Event of Default shall be deemed a continuing representation until the resulting Event of Default is cured or otherwise ceases to exist or the Notes are accelerated. In addition, each Directing Holder is deemed, at the time of providing a Noteholder Direction, to covenant to provide the Company with such other information as the Company may reasonably request from time to time in order to verify the accuracy of such noteholder’s Position Representation within five Business Days of request therefor (a “Verification Covenant”). In any case in which the noteholder is DTC, or its nominee, any Position Representation or Verification Covenant required hereunder shall be provided by the beneficial owner of the Notes in lieu of DTC, or its nominee, and DTC shall be entitled to conclusively rely on such Position Representation and Verification Covenant in delivering its direction to the Trustee.

 

115


If, following the delivery of a Noteholder Direction, but prior to acceleration of the Notes, the Company determines in good faith that there is a reasonable basis to believe a Directing Holder was, at any relevant time, in breach of its Position Representation and provides to the Trustee an Officer’s Certificate stating that the Company has initiated litigation in a court of competent jurisdiction seeking a determination that such Directing Holder was, at such time, in breach of its Position Representation, and seeking to invalidate any Event of Default that resulted from the applicable Noteholder Direction, the cure period with respect to such Event of Default shall be automatically stayed and the cure period with respect to such Event of Default shall be automatically reinstituted and any remedy stayed pending a final and non-appealable determination of a court of competent jurisdiction on such matter (a “Court Determination”). If, following the delivery of a Noteholder Direction, but prior to acceleration of the Notes, the Company provides to the Trustee an Officer’s Certificate stating that a Directing Holder failed to satisfy its Verification Covenant, the cure period with respect to such Event of Default shall be automatically stayed and the cure period with respect to any Event of Default that resulted from the applicable Noteholder Direction shall be automatically reinstituted and any remedy stayed pending satisfaction of such Verification Covenant, and confirmation of such satisfaction shall be provided in writing by the Company to the Trustee. Any breach of the Position Representation (as confirmed by a Court Determination) shall result in such noteholder’s participation in such Noteholder Direction being disregarded; and, if, without the participation of such noteholder, the percentage of Notes held by the remaining Holders that provided such Noteholder Direction would have been insufficient to validly provide such Noteholder Direction, such Noteholder Direction shall be void ab initio, with the effect that such Event of Default shall be deemed never to have occurred, acceleration voided and the Trustee shall be deemed not to have received such Noteholder Direction or any notice of such Event of Default; provided, however, that this shall not invalidate any indemnity or security provided by any Directing Holder to the Trustee.

Notwithstanding anything in the preceding two paragraphs to the contrary, any Noteholder Direction delivered to the Trustee during the pendency of an Event of Default as the result of a bankruptcy or similar proceeding shall not require compliance with the foregoing paragraphs. For the avoidance of doubt, the Trustee shall be entitled to conclusively rely on any Noteholder Direction, Position Representation, Verification Covenant, Officer’s Certificate or other document delivered to it in accordance with this Indenture, shall have no duty to monitor, inquire as to or investigate the accuracy of, or compliance with, any Position Representation or any Verification Covenant, verify any statements in any Officer’s Certificate delivered to it, or otherwise make calculations, investigations or determinations or take any other actions with respect to Derivative Instruments, Net Shorts, Long Derivative Instruments, Short Derivative Instruments or otherwise. The Trustee shall have no liability to the Company, any noteholder or any other Person in acting in good faith pursuant to a Noteholder Direction without regard to any Position Representation or compliance with any Verification Covenant, and all such parties agree not to commence any legal proceedings against the Trustee in respect of, and agree that the Trustee will not be liable for, the delivery and accuracy of, or compliance with, any Position Representation or any Verification Covenant. A Position Representation may be substantially in the form of Exhibit H hereto with such other changes and information as reasonably requested by the Company and the Trustee, if applicable.

 

116


Section 6.06 Control by Majority.

Holders of more than 50% in aggregate principal amount of the then outstanding Notes of such series may direct the time, method and place of conducting any proceeding for exercising any remedy available to the Trustee or exercising any trust or power conferred on it. However, the Trustee may refuse to follow any direction that conflicts with law or this Indenture that the Trustee determines may be unduly prejudicial to the rights of other Holders or that may involve the Trustee in personal liability.

Section 6.07 Rights of Holders to Receive Payment.

Notwithstanding any other provision of this Indenture and subject to Section 6.12 hereof, the right of any Holder of a Note to receive payment of principal, premium, and interest on the Note, on or after the respective due dates expressed in the Note (including in connection with an offer to purchase), or to bring suit for the enforcement of any such payment on or after such respective dates, shall not be impaired or affected without the consent of such Holder; provided that a Holder shall not have the right to institute any such suit for the enforcement of payment if and to the extent that the institution or prosecution thereof or the entry of judgment therein would, under applicable law, result in the surrender, impairment, waiver or loss of the Lien of this Indenture upon any property subject to such Lien.

Section 6.08 Collection Suit by Trustee.

If an Event of Default specified in Section 6.01(a) with respect to the Notes occurs and is Continuing, the Trustee is authorized to recover judgment in its own name and as trustee of an express trust against the Company for the whole amount of principal of, premium, and interest remaining unpaid on, the Notes and interest on overdue principal and, to the extent lawful, interest and such further amount as shall be sufficient to cover the costs and expenses of collection, including the reasonable compensation, expenses, disbursements and advances of the Trustee, its agents and counsel.

Section 6.09 Trustee May File Proofs of Claim.

The Trustee is authorized to file such proofs of claim and other papers or documents as may be necessary or advisable in order to have the claims of the Trustee (including any claim for the reasonable compensation, expenses, disbursements and advances of the Trustee, its agents and counsel) and the Holders allowed in any judicial proceedings relative to the Company (or any other obligor upon the Notes), its creditors or its property and shall be entitled and empowered to collect, receive and distribute any money or other property payable or deliverable on any such claims and any custodian in any such judicial proceeding is hereby authorized by each Holder to make such payments to the Trustee, and in the event that the Trustee shall consent to the making of such payments directly to the Holders, to pay to the Trustee any amount due to it for the reasonable compensation, expenses, disbursements and advances of the Trustee, its agents and counsel, and any other amounts due the Trustee under Section 7.07. To the extent that the payment of any such compensation, expenses, disbursements and advances of the Trustee, its agents and counsel, and

 

117


any other amounts due the Trustee under Section 7.07 out of the estate in any such proceeding, shall be denied for any reason, payment of the same shall be secured by a Lien on, and shall be paid out of, any and all distributions, dividends, money, securities and other properties that the Holders may be entitled to receive in such proceeding whether in liquidation or under any plan of reorganization or arrangement or otherwise. Nothing herein contained shall be deemed to authorize the Trustee to authorize or consent to or accept or adopt on behalf of any Holder any plan of reorganization, arrangement, adjustment or composition affecting the Notes or the rights of any Holder, or to authorize the Trustee to vote in respect of the claim of any Holder in any such proceeding.

Section 6.10 Priorities.

If the Trustee collects any money pursuant to this Article 6, or, after an Event of Default, any money or other property distributable in respect of the Company’s obligations under this Indenture, it shall pay out the money in the following order:

First: to the Trustee (including any predecessor trustee), its agents and attorneys for amounts due under Section 7.07, including payment of all compensation, expenses and liabilities incurred, and all advances made, by the Trustee and the costs and expenses of collection;

Second: to Holders for amounts due and unpaid on the Notes for principal, premium and interest, ratably, without preference or priority of any kind, according to the amounts due and payable on the Notes for principal, premium and interest, respectively; and

Third: to the Company or to such party as a court of competent jurisdiction shall direct.

The Trustee may fix a record date and payment date for any payment to Holders pursuant to this Section 6.10.

Section 6.11 Undertaking for Costs.

In any suit for the enforcement of any right or remedy under this Indenture or in any suit against the Trustee for any action taken or omitted by it as a Trustee, a court in its discretion may require the filing by any party litigant in the suit of an undertaking to pay the costs of the suit, and the court in its discretion may assess reasonable costs, including reasonable attorneys’ fees, against any party litigant in the suit, having due regard to the merits and good faith of the claims or defenses made by the party litigant. This Section 6.11 does not apply to a suit by the Trustee, a suit by a Holder of a Note pursuant to Section 6.07, or a suit by Holders of more than 10% in aggregate principal amount of the then outstanding Notes of such series.

6.12 Applicability of the CSAA.

In all cases of the pursuit of a remedy or an enforcement of the performance of any provision of this Indenture by the Trustee or by Holders if permitted under this Indenture, the Trustee and each Holder hereby consent and agree under this Indenture that, subject to any non-waivable rights held by a Holder with respect to pursuit of remedies under Applicable Law, any

 

118


pursuit of a remedy or enforcement pursued under or pursuant to the Indenture, the Notes or the Note Guarantees shall be subject to the terms and conditions of the CSAA. The Trustee and Holders agree that if Holders meet the criteria in this Indenture to pursue a remedy or enforcement of the performance of any provision of this Indenture directly, they shall be deemed to be doing so on behalf of the Trustee (in its capacity as Senior Creditor Group Representative of the Holders under this Indenture) for purposes of the CSAA and, in pursuit of such remedy or enforcement of the performance of any provision of this Indenture, shall be subject to the terms and conditions of the CSAA.

ARTICLE 7

TRUSTEE

Section 7.01 Duties of Trustee.

(a) If an Event of Default has occurred and is Continuing, the Trustee will exercise such of the rights and powers vested in it by this Indenture, and use the same degree of care and skill in their exercise, as a prudent person would exercise or use under the circumstances in the conduct of such person’s own affairs.

(b) Except during the Continuance of an Event of Default:

(1) the duties of the Trustee will be determined solely by the express provisions of this Indenture and the Trustee need perform only those duties that are specifically set forth in this Indenture and no others, and no implied covenants or obligations shall be read into this Indenture against the Trustee; and

(2) in the absence of bad faith on its part, the Trustee may conclusively rely, as to the truth of the statements and the correctness of the opinions expressed therein, upon certificates or opinions furnished to the Trustee and conforming to the requirements of this Indenture. However, in the case of any such certificates or opinions which by any provision hereof are specifically required to be furnished to the Trustee, the Trustee will examine the certificates and opinions to determine whether or not they conform to the requirements of this Indenture (but need not confirm or investigate the accuracy of mathematical calculations or other facts, statements, opinions or conclusions stated therein).

(c) The Trustee may not be relieved from liabilities for its own negligent action, its own negligent failure to act, or its own willful misconduct, except that:

(1) this paragraph does not limit the effect of paragraphs (b) and (e) of this Section 7.01;

(2) the Trustee will not be liable for any error of judgment made in good faith by a Responsible Officer, unless it is proved that the Trustee was negligent in ascertaining the pertinent facts; and

(3) the Trustee will not be liable with respect to any action it takes or omits to take in good faith in accordance with a direction received by it pursuant to Section 6.05.

 

119


(d) Whether or not therein expressly so provided, every provision of this Indenture that in any way relates to the Trustee is subject to this Section 7.01.

(e) No provision of this Indenture will require the Trustee to expend or risk its own funds or incur any liability. The Trustee will be under no obligation to exercise any of its rights and powers under this Indenture at the request of any Holders, unless such Holder has offered to the Trustee security and indemnity satisfactory to it against any loss, liability or expense.

(f) The Trustee will not be liable for interest on any money received by it except as the Trustee may agree in writing with the Company. Money held in trust by the Trustee need not be segregated from other funds except to the extent required by law.

Section 7.02 Rights of Trustee.

(a) The Trustee may conclusively rely upon any resolution, certificate, statement, instrument, opinion, report, notice, request, direction, consent, order, bond, debenture, note, other evidence of indebtedness or other paper or document believed by it to be genuine and to have been signed or presented by the proper party or parties. The Trustee need not investigate any fact or matter stated in any resolution, certificate, statement, instrument, opinion, report, notice, request, direction, consent, order, bond, debenture, note, other evidence of indebtedness or other paper or document, but the Trustee, in its discretion, may make such further inquiry or investigation into such facts or matters as it may see fit, and, if the Trustee shall determine to make such further inquiry or investigation, it shall be entitled to examine the books, records and premises of the Company, personally or by agent or attorney at the sole cost of the Company and shall incur no liability or additional liability of any kind by reason of such inquiry or investigation.

(b) Before the Trustee acts or refrains from acting, it may require an Officer’s Certificate or an Opinion of Counsel or both; provided that an Officer’s Certificate or Opinion of Counsel will not be required if the Indenture requires the Company to deliver a certificate of an Authorized Officer of the Company in connection with such act or refrain from acting. The Trustee will not be liable for any action it takes, suffers or omits to take in good faith in reliance on such Officer’s Certificate, Opinion of Counsel or a certificate of an Authorized Officer of the Company. The Trustee may consult with counsel and the advice of such counsel or any Opinion of Counsel will be full and complete authorization and protection from liability in respect of any action taken, suffered or omitted by it hereunder in good faith and in reliance thereon.

(c) The Trustee may act through its attorneys and agents and will not be responsible for the misconduct or negligence of any agent appointed with due care.

(d) The Trustee will not be liable for any action it takes, suffers or omits to take in good faith that it believes to be authorized or within the rights or powers conferred upon it by this Indenture.

(e) Unless otherwise specifically provided in this Indenture, any demand, request, direction or notice from the Company will be sufficient if signed by an Officer of the Company.

(f) The Trustee will be under no obligation to exercise any of the rights or powers vested in it by this Indenture at the request or direction of any of the Holders unless such Holders have offered to the Trustee indemnity or security satisfactory to the Trustee against the losses, liabilities and expenses that might be incurred by it in compliance with such request or direction.

 

120


(g) The Trustee shall not be deemed to have notice of any Unmatured Event of Default or Event of Default unless a Responsible Officer of the Trustee has written notice thereof or unless written notice of such Unmatured Event of Default or Event of Default is received by a Responsible Officer of the Trustee at the Corporate Trust Office of the Trustee, and such notice references the Notes and this Indenture.

(h) The Trustee shall not be responsible or liable for any failure or delay in the performance of its obligations under this Indenture arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; fire; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; interruptions; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; labor disputes; acts of civil or military authority and governmental action.

(i) The rights, privileges, protections, immunities and benefits given to the Trustee, including, without limitation, its right to be indemnified, are extended to, and shall be enforceable by, the Trustee in each of its capacities hereunder (and under the other Finance Documents to which it is a party) and each agent, custodian and other Person employed to act hereunder or thereunder.

(j) The Trustee shall not be liable for any action taken, suffered, or omitted to be taken by it in good faith and reasonably believed by it to be authorized or within the discretion or rights or powers conferred upon it by this Indenture.

(k) The Trustee may request that the Company deliver a certificate setting forth the names of individuals and/or titles of officers authorized at such time to take specified actions pursuant to this Indenture, which certificate may be signed by any person authorized to sign an Officer’s Certificate, including any person specified as so authorized in any such certificate previously delivered and not superseded.

(l) Anything in this Indenture notwithstanding, in no event shall the Trustee be liable for special, indirect, punitive or consequential or other similar loss or damage of any kind whatsoever (including but not limited to loss of profit), even if the Trustee has been advised as to the likelihood of such loss or damage and regardless of the form of action.

(m) In order to comply with applicable tax laws, rules and regulations (inclusive of directives, guidelines and interpretations promulgated by competent authorities) in effect from time to time (“Applicable Tax Law”) related to this Indenture, the Company agrees (i) to provide to the Trustee information about holders or other applicable parties and/or transactions (including any modification to the terms of such transactions) that is within the possession of the Company and reasonably requested by the Trustee so the Trustee can determine whether it has tax related obligations under Applicable Tax Law, (ii) that the Trustee shall be entitled to make any withholding or deduction from payments under this Indenture to the extent necessary to comply with Applicable Tax Law for which the Trustee shall not have any liability, and (iii) to indemnify and hold harmless the Trustee for any losses it may suffer due to the actions it takes to comply with such Applicable Tax Law. The terms of this section shall survive the termination of this Indenture.

 

121


Section 7.03 Individual Rights of Trustee.

The Trustee in its individual or any other capacity may become the owner or pledgee of Notes and may otherwise deal with the Company or any Affiliate of the Company with the same rights it would have if it were not Trustee. However, in the event that the Trustee acquires any conflicting interest (as defined in Section 310(b) of the TIA) it must eliminate such conflict within 90 days or resign. Any Agent may do the same with like rights and duties. The Trustee is also subject to Sections 7.10.

Section 7.04 Trustee’s Disclaimer.

The Trustee will not be responsible for and makes no representation as to the validity or adequacy of this Indenture or the Notes, it shall not be accountable for the Company’s use of the proceeds from the Notes or any money paid to the Company or upon the Company’s direction under any provision of this Indenture, it will not be responsible for the use or application of any money received by any Paying Agent other than the Trustee, and it will not be responsible for any statement or recital herein or any statement in the Notes or any other document in connection with the sale of the Notes or pursuant to this Indenture other than its certificate of authentication.

The Trustee will not be responsible for the existence, genuineness or value of any of the Collateral, for the validity, perfection, priority or enforceability of the Liens in any of the Collateral, whether impaired by operation of law or by reason of any action or omission to act on its part hereunder, except to the extent such action or omission constitutes gross negligence, bad faith or willful misconduct on the part of the Trustee, for the validity or sufficiency of the Collateral or any agreement or assignment contained therein, for the validity of the title of the Company or the Pledgor to the Collateral, for insuring the Collateral or for the payment of taxes, charges, assessments or Liens upon the Collateral or otherwise as to the maintenance of the Collateral. The Trustee hereby disclaims any representation or warranty to the present and future holders of the Secured Obligations concerning the perfection of the Liens granted hereunder or in the value of any of the Collateral. For purposes of the two preceding sentences, the terms “Collateral,” “Liens,” “Pledgor” and “Secured Obligations” shall have the meanings ascribed to such terms in the Collateral Trust Agreement.

Section 7.05 Notice of Defaults.

If an Unmatured Event of Default or Event of Default occurs and is Continuing and if a Responsible Officer of the Trustee has written notice thereof, the Trustee will mail to Holders a notice of the Unmatured Event of Default or Event of Default within 90 days after it occurs. Except in the case of an Unmatured Event of Default or Event of Default in payment of principal of, premium or interest on, any Note, the Trustee may withhold the notice if and so long as a committee of its Responsible Officers in good faith determines that withholding the notice is in the interests of the Holders.

 

122


Section 7.06 [Reserved].

Section 7.07 Compensation and Indemnity.

(a) The Company will pay to the Trustee from time to time reasonable compensation for its acceptance of this Indenture and services hereunder. The Trustee’s compensation will not be limited by any law on compensation of a trustee of an express trust. The Company will reimburse the Trustee promptly upon request for all reasonable disbursements, advances and expenses incurred or made by it in addition to the compensation for its services. Such expenses will include the reasonable compensation, disbursements and expenses of the Trustee’s agents and counsel and of all Persons not regularly in its employ.

(b) The Company and the Guarantors will indemnify each of the Trustee or any predecessor trustee and their officers, agents, directors and employees for, and hold them harmless against, any and all loss, damage, claims, liability or expense, including taxes (other than taxes based upon, measured by or determined by the income of the Trustee), incurred by it arising out of or in connection with the acceptance or administration of its duties under this Indenture and the Finance Documents, including the costs and expenses of enforcing this Indenture against the Company and the Guarantors (including this Section 7.07) and defending itself against any claim (whether asserted by the Company, the Guarantors, any Holder or any other Person) or liability in connection with the exercise or performance of any of its powers or duties hereunder or thereunder, except to the extent any such loss, liability or expense may be attributable to its gross negligence or willful misconduct. The Trustee will notify the Company promptly of any claim for which it may seek indemnity. Failure by the Trustee to so notify the Company will not relieve the Company or any of the Guarantors of their obligations hereunder. The Company or such Guarantor will defend the claim and the Trustee will cooperate in the defense. The Trustee may have separate counsel and the Company will pay the reasonable fees and expenses of such counsel. Neither the Company nor any Guarantor need pay for any settlement made without its consent, which consent will not be unreasonably withheld.

(c) The obligations of the Company and the Guarantors under this Section 7.07 will survive the satisfaction and discharge of this Indenture, the termination for any reason of this Indenture and the resignation or removal of the Trustee.

(d) To secure the Company’s and the Guarantors’ payment obligations in this Section 7.07, the Trustee will have a Lien prior, to the extent set forth under the CSAA, to the Notes on all money or property held or collected by the Trustee, except that held in trust to pay principal and interest on particular Notes. Such Lien will survive the satisfaction and discharge of this Indenture, the termination for any reason of this Indenture and the resignation or removal of the Trustee.

(e) When the Trustee incurs expenses or renders services after an Event of Default specified in Section 6.01(c)(i) occurs, the expenses and the compensation for the services (including the fees and expenses of its agents and counsel) are intended to constitute expenses of administration under any Bankruptcy Law.

 

123


(f) “Trustee” for purposes of this Section shall include any predecessor Trustee; provided, however, that the negligence, willful misconduct or bad faith of any Trustee hereunder shall not affect the rights of any other Trustee hereunder.

Section 7.08 Replacement of Trustee.

(a) A resignation or removal of the Trustee and appointment of a successor Trustee will become effective only upon the successor Trustee’s acceptance of appointment as provided in this Section 7.08.

(b) The Trustee may resign in writing at any time and be discharged from the trust hereby created by so notifying the Company. The Holders of more than 50% in aggregate principal amount of the then outstanding Notes may remove the Trustee by so notifying the Trustee and the Company in writing. The Company may remove the Trustee if:

(1) the Trustee fails to comply with Section 7.10;

(2) the Trustee is adjudged a bankrupt or an insolvent or an order for relief is entered with respect to the Trustee under any Bankruptcy Law;

(3) a custodian or public officer takes charge of the Trustee or its property; or

(4) the Trustee becomes incapable of acting.

(c) If the Trustee resigns or is removed or if a vacancy exists in the office of Trustee for any reason, the Company will promptly appoint a successor Trustee. Within one year after the successor Trustee takes office, the Holders of more than 50% in aggregate principal amount of the then outstanding Notes may appoint a successor Trustee to replace the successor Trustee appointed by the Company.

(d) If a successor Trustee does not take office within 60 days after the retiring Trustee resigns or is removed, the retiring Trustee, the Company, or the Holders of at least 10% in aggregate principal amount of the then outstanding Notes may petition any court of competent jurisdiction for the appointment of a successor Trustee.

(e) If the Trustee, after written request by any Holder who has been a Holder for at least six months, fails to comply with Section 7.10, such Holder may petition any court of competent jurisdiction for the removal of the Trustee and the appointment of a successor Trustee.

(f) A successor Trustee will deliver a written acceptance of its appointment to the retiring Trustee and to the Company. Thereupon, the resignation or removal of the retiring Trustee will become effective, and the successor Trustee will have all the rights, powers and duties of the Trustee under this Indenture. The successor Trustee will mail a notice of its succession to Holders. The retiring Trustee will promptly transfer all property held by it as Trustee to the successor Trustee; provided all sums owing to the Trustee hereunder have been paid and subject to the Lien provided for in Section 7.07. Notwithstanding replacement of the Trustee pursuant to this Section 7.08, the Company’s obligations under Section 7.07 will continue for the benefit of the retiring Trustee.

 

124


Section 7.09 Successor Trustee by Merger, etc.

If the Trustee consolidates, merges or converts into, or transfers all or substantially all of its corporate trust business to, another Person, the successor Person without any further act will be the successor Trustee. In case any Notes shall have been authenticated but not delivered by the Trustee then in office, any successor by merger, conversion or consolidation to such authenticating Trustee may adopt such authentication and deliver the Notes so authenticated with the same effect as if such successor Trustee had itself authenticated such Notes.

Section 7.10 Eligibility; Disqualification.

There will at all times be a Trustee hereunder that is a Person organized and doing business under the laws of the United States of America or of any state thereof that is authorized under such laws to exercise corporate trustee power, that is subject to supervision or examination by federal or state authorities and that has a combined capital and surplus of at least $100,000,000 as set forth in its most recent published annual report of condition.

Section 7.11 Authorization to Enter Into Accession Agreement.

The Trustee is hereby authorized and directed by each of Holder of the Initial Notes to enter into the Accession Agreement and to exercise all the rights and perform all the obligations of a Secured Debt Holder Group Representative set out in the applicable Finance Documents, including, without limitation, making, on behalf of the Holders, any amendments or modifications as described in Section 9.03 and the agreements expressed to be made by Secured Debt Holders under the Finance Documents.

Section 7.12 Trustee Protective Provisions.

Without duplication of any amounts the Trustee is entitled to recover under any indemnification provisions in the Finance Documents, the rights, privileges, protections, indemnities, immunities and benefits provided to the Trustee in this Indenture are in addition to, and are not intended to be in conflict with or limited by, any such provisions in the Finance Documents.

ARTICLE 8

LEGAL DEFEASANCE AND COVENANT DEFEASANCE

Section 8.01 Option to Effect Legal Defeasance or Covenant Defeasance.

The Company may at any time, at the option of its Board of Directors (or equivalent governing body) evidenced by a resolution set forth in an Officer’s Certificate, elect to have either Section 8.02 or 8.03 be applied to all outstanding Notes of any series upon compliance with the conditions set forth below in this Article 8.

 

125


Section 8.02 Legal Defeasance and Discharge.

Upon the Company’s exercise under Section 8.01 of the option applicable to this Section 8.02, the Company and each of the Guarantors will, subject to the satisfaction of the conditions set forth in Section 8.04, be deemed to have been discharged from their obligations with respect to all outstanding Notes of such series (including the Note Guarantees) on the date the conditions set forth below are satisfied (hereinafter, “Legal Defeasance”). For this purpose, Legal Defeasance means that the Company and the Guarantors will be deemed to have paid and discharged the entire Indebtedness represented by the outstanding Notes of such series (including the Note Guarantees), which will thereafter be deemed to be “outstanding” only for the purposes of Section 8.05 and the other Sections of this Indenture referred to in clauses (1) and (2) below, and to have satisfied all their other obligations under such Notes, the Note Guarantees and this Indenture (and the Trustee, on demand of and at the expense of the Company, shall execute proper instruments acknowledging the same), except for the following provisions which will survive until otherwise terminated or discharged hereunder:

(1) the rights of Holders of outstanding Notes of such series to receive payments in respect of the principal of, or interest or premium, if any, on, such Notes when such payments are due from the trust referred to in Section 8.04;

(2) the Company’s obligations with respect to such Notes under Article 2 and Section 4.02;

(3) the rights, powers, trusts, duties and immunities of the Trustee hereunder and the Company’s and the Guarantors’ obligations in connection therewith; and

(4) this Article 8.

Subject to compliance with this Article 8, the Company may exercise its option under this Section 8.02 notwithstanding the prior exercise of its option under Section 8.03.

Section 8.03 Covenant Defeasance.

Upon the Company’s exercise under Section 8.01 of the option applicable to this Section 8.03, the Company and each of the Guarantors will, subject to the satisfaction of the conditions set forth in Section 8.04, be released from each of their obligations under the covenants contained in Section 4.06 through Section 4.45 and Section 5.01(c) with respect to the outstanding Notes of such series on and after the date the conditions set forth in Section 8.04 are satisfied (hereinafter, “Covenant Defeasance”), and the Notes of such series will thereafter be deemed not “outstanding” for the purposes of any direction, waiver, consent or declaration or act of Holders (and the consequences of any thereof) in connection with such covenants, but will continue to be deemed “outstanding” for all other purposes hereunder (it being understood that such Notes will not be deemed outstanding for accounting purposes).

For this purpose, Covenant Defeasance means that, with respect to the outstanding Notes and Note Guarantees, the Company and the Guarantors may omit to comply with and will have no liability in respect of any term, condition or limitation set forth in any such covenant, whether directly or indirectly, by reason of any reference elsewhere herein to any such covenant or by

 

126


reason of any reference in any such covenant to any other provision herein or in any other document and such omission to comply will not constitute an Unmatured Event of Default or Event of Default under Section 6.01, but, except as specified above, the remainder of this Indenture and such Notes and Note Guarantees will be unaffected thereby. In addition, upon the Company’s exercise under Section 8.01 of the option applicable to this Section 8.03, subject to the satisfaction of the conditions set forth in Section 8.04, Section 6.01(b) through Section 6.01(d) will not constitute Events of Default.

Section 8.04 Conditions to Legal or Covenant Defeasance.

In order to exercise either Legal Defeasance or Covenant Defeasance under either Section 8.02 or 8.03:

(1) the Company must irrevocably deposit with the Trustee, in trust, for the benefit of the Holders, cash in U.S. dollars, non-callable Government Securities, or a combination thereof, in such amounts as will be sufficient, without reinvestment, in the opinion of, or as certified by, a nationally recognized investment bank, appraisal firm, or firm of independent public accountants, to pay the principal of, and interest and premium on, the outstanding Notes of such series on the stated date for payment thereof or on the applicable redemption date, as the case may be, and the Company must specify whether the Notes of such series are being defeased to such stated date for payment or to a particular redemption date;

(2) in the case of an election under Section 8.02, the Company has delivered to the Trustee an Opinion of Counsel confirming that:

(A) the Company has received from, or there has been published by, the Internal Revenue Service a ruling; or

(B) since the Notes Issue Date, there has been a change in the applicable federal income tax law,

(C) in either case to the effect that, and based thereon such Opinion of Counsel shall confirm that, the Holders of the outstanding Notes of such series will not recognize income, gain or loss for federal income tax purposes as a result of such Legal Defeasance and will be subject to federal income tax on the same amounts, in the same manner and at the same times as would have been the case if such Legal Defeasance had not occurred;

(3) in the case of an election under Section 8.03, the Company must deliver to the Trustee an Opinion of Counsel confirming that the Holders of the outstanding Notes of such series will not recognize income, gain or loss for federal income tax purposes as a result of such Covenant Defeasance and will be subject to federal income tax on the same amounts, in the same manner and at the same times as would have been the case if such Covenant Defeasance had not occurred;

 

127


(4) no Unmatured Event of Default or Event of Default shall have occurred and be Continuing on the date of such deposit (other than an Unmatured Event of Default or Event of Default resulting from the borrowing of funds to be applied to such deposit) and the deposit will not result in a breach or violation of, or constitute a default under, any other instrument to which the Company or any Guarantor is a party or by which the Company or any Guarantor is bound;

(5) such Legal Defeasance or Covenant Defeasance will not result in a breach or violation of, or constitute a default under, any material agreement or instrument (other than this Indenture) to which the Company, TCP or any of their respective Subsidiaries is a party or by which the Company, TCP or any of their respective Subsidiaries is bound;

(6) the Company must deliver to the Trustee an Officer’s Certificate stating that the deposit was not made by the Company with the intent of preferring the Holders of such series over the other creditors of the Company with the intent of defeating, hindering, delaying or defrauding creditors of the Company or others;

(7) the Company must deliver to the Trustee an Officer’s Certificate stating that all conditions precedent set forth in clauses (1) through (6) of this Section 8.04 have been complied with; and

(8) the Company must deliver to the Trustee an Opinion of Counsel (which Opinion of Counsel may be subject to customary assumptions, qualifications and exclusions), stating that all conditions precedent set forth in clauses (2), (3) and (5) of this Section 8.04 have been complied with; provided that, the Opinion of Counsel with respect to clause (5) of this Section 8.04 may be to the knowledge of such counsel.

Section 8.05 Deposited Money and Government Securities to be Held in Trust; Other Miscellaneous Provisions.

Subject to Section 8.06, all money and non-callable Government Securities (including the proceeds thereof) deposited with the Trustee (or other qualifying trustee, collectively for purposes of this Section 8.05, the “Trustee”) pursuant to Section 8.04 in respect of the outstanding Notes will be held in trust and applied by the Trustee, in accordance with the provisions of such Notes and this Indenture, to the payment, either directly or through any Paying Agent (including the Company acting as Paying Agent) as the Trustee may determine, to the Holders of such Notes of all sums due and to become due thereon in respect of principal, premium, if any, and interest, but such money need not be segregated from other funds except to the extent required by law.

The Company will pay and indemnify the Trustee against any tax, fee or other charge imposed on or assessed against the cash or non-callable Government Securities deposited pursuant to Section 8.04 or the principal and interest received in respect thereof other than any such tax, fee or other charge which by law is for the account of the Holders of the outstanding Notes.

Notwithstanding anything in this Article 8 to the contrary, the Trustee will deliver or pay to the Company from time to time upon the request of the Company any money or non-callable Government Securities held by it as provided in Section 8.04 which, in the opinion of a nationally recognized firm of independent public accountants expressed in a written certification thereof delivered to the Trustee (which may be the opinion delivered under Section 8.04(1)), are in excess of the amount thereof that would then be required to be deposited to effect an equivalent Legal Defeasance or Covenant Defeasance.

 

128


Section 8.06 Repayment to Company.

Any money deposited with the Trustee or any Paying Agent, or then held by the Company, in trust for the payment of the principal of, premium or interest on, any Note and remaining unclaimed for two years after such principal, premium or interest has become due and payable shall be paid to the Company on its request or (if then held by the Company) will be discharged from such trust; and the Holder of such Note will thereafter be permitted to look only to the Company for payment thereof, and all liability of the Trustee or such Paying Agent with respect to such trust money, and all liability of the Company as trustee thereof, will thereupon cease; provided, however, that the Trustee or such Paying Agent, before being required to make any such repayment, may at the expense of the Company cause to be published once, in the New York Times and The Wall Street Journal (national edition), notice that such money remains unclaimed and that, after a date specified therein, which will not be less than 30 days from the date of such notification or publication, any unclaimed balance of such money then remaining will be repaid to the Company.

Section 8.07 Reinstatement.

If the Trustee or Paying Agent is unable to apply any U.S. dollars or non-callable Government Securities in accordance with Section 8.02 or 8.03, as the case may be, by reason of any order or judgment of any court or Governmental Authority enjoining, restraining or otherwise prohibiting such application, then the Company’s and the Guarantors’ obligations under this Indenture and the Notes and the Note Guarantees will be revived and reinstated as though no deposit had occurred pursuant to Section 8.02 or 8.03 until such time as the Trustee or Paying Agent is permitted to apply all such money in accordance with Section 8.02 or 8.03, as the case may be; provided, however, that, if the Company makes any payment of principal of, premium or interest on, any Note following the reinstatement of its obligations, the Company will be subrogated to the rights of the Holders of such Notes to receive such payment from the money held by the Trustee or Paying Agent.

ARTICLE 9

AMENDMENT, SUPPLEMENT AND WAIVER

Section 9.01 Without Consent of Holders.

Notwithstanding Section 9.02, the Company, the Guarantors and the Trustee may amend or supplement the Notes and this Indenture or the Note Guarantees without the consent of any Holder or any Rating Reaffirmation:

(1) to cure any ambiguity, omission, mistake, defect or inconsistency;

(2) to add covenants or defaults to this Indenture;

 

129


(3) to modify the restrictive legends set forth on the face of the form of any series of Notes or modify the forms of certification;

(4) to make any change that would provide any additional rights or benefits to Holders, increase the interest rate applicable to the Notes or that does not adversely affect the legal rights under this Indenture of any Holder;

(5) to conform the text of this Indenture, the Note Guarantees or the Notes to any provision under the “Description of Senior Notes” section of the Offering Memorandum to the extent that such provision was intended to be a verbatim or substantially verbatim recitation of a provision of any of the foregoing;

(6) to add additional assets as Collateral;

(7) to provide for uncertificated Notes in addition to or in place of certificated Notes (provided, however, that such uncertificated Notes are in “registered” form within the meaning of section 163 of the Internal Revenue Code of 1986, as amended, and Treasury regulations thereunder);

(8) to provide for assumption of an Obligor’s obligations by a successor pursuant to this Indenture;

(9) to release a Guarantor from its Note Guarantee and terminate such Note Guarantee in accordance with this Indenture;

(10) to comply with the requirements of the SEC in order to effect or maintain the qualification of this Indenture under the TIA;

(11) to add any Note Guarantee;

(12) to provide for the issuance of Additional Notes in accordance with the limitations set forth in this Indenture as of the Notes Issue Date;

(13) to evidence the succession of a new Trustee for any series of Notes; or

(14) to change or modify any provision or definition from the CSAA, included or referred to in this Indenture, the Note Guarantees or the Notes, as applicable, to the extent such provision or definition is changed or modified in the CSAA either (I) pursuant to Section 9.03 or (II) as otherwise permitted under the CSAA.

Upon the request of the Company accompanied by a resolution of its Board of Directors authorizing the execution of any such amended or supplemental indenture, and upon receipt by the Trustee of the documents described in Section 7.02, the Trustee will join with the Company and the Guarantors in the execution of any amended or supplemental indenture authorized or permitted by the terms of this Indenture and to make any further appropriate agreements and stipulations that may be therein contained. Any such amendment or waiver that imposes any obligation upon the Trustee or adversely affects the rights of the Trustee in its individual capacity will become effective only with the consent of the Trustee.

 

130


Section 9.02 With Consent of Holders.

Except as provided below in this Section 9.02, the Company and the Trustee may amend or supplement this Indenture (including Section 3.09, Section 4.12, Section 4.17, Section 4.19, Section 4.20, and Section 4.21) and the Notes and the Note Guarantees with the consent of the Holders of more than 50% in aggregate principal amount of the then outstanding Notes (including, without limitation, Additional Notes, if any) voting as a single class, or if such amendment or supplement relates solely to Notes of a particular series, the Holders of more than 50% in principal amount of the Notes of such series then outstanding (including consents obtained in connection with a tender offer or exchange offer for, or purchase of, the Notes), and, subject to Sections 6.04 and Section 6.07, any existing Unmatured Event of Default or Event of Default (other than an Unmatured Event of Default or Event of Default in the payment of the principal of, premium or interest on, the Notes of such series, except a payment default resulting from an acceleration that has been rescinded) or compliance with any provision of this Indenture or the Notes or the Note Guarantees may be waived with the consent of the Holders of more than 50% in aggregate principal amount of the then outstanding Notes (including, without limitation, Additional Notes, if any) voting as a single class (including, without limitation, consents obtained in connection with a tender offer or exchange offer for, or purchase of, the Notes of such series). Section 2.08 shall determine which Notes of such series are considered to be “outstanding” for purposes of this Section 9.02.

Upon the request of the Company accompanied by a resolution of its Board of Directors (or equivalent governing body) authorizing the execution of any such amended or supplemental indenture, and upon the filing with the Trustee of evidence satisfactory to the Trustee of the consent of the Holders as aforesaid, and upon receipt by the Trustee of the documents described in Section 7.02, the Trustee will join with the Company and the Guarantors in the execution of such amended or supplemental indenture unless such amended or supplemental indenture directly affects the Trustee’s own rights, duties or immunities under this Indenture or otherwise, in which case the Trustee may in its discretion, but will not be obligated to, enter into such amended or supplemental Indenture.

It is not be necessary for the consent of the Holders under this Section 9.02 to approve the particular form of any proposed amendment, supplement or waiver, but it is sufficient if such consent approves the substance thereof.

After an amendment, supplement or waiver under this Section 9.02 becomes effective, the Company will deliver to the Holders affected thereby a notice briefly describing the amendment, supplement or waiver. Any failure of the Company to deliver such notice, or any defect therein, will not, however, in any way impair or affect the validity of any such amended or supplemental indenture or waiver. Subject to Sections 6.04 and Section 6.07, the Holders of more than 50% in aggregate principal amount of the Notes (or if a waiver relates to less than all series of Notes, of such series then outstanding) voting as a single class may waive compliance in a particular instance by the Company with any provision of this Indenture or the Notes (or the Notes of such series, as applicable) or the Note Guarantees. However, without the consent of each Holder of each series of Notes affected, an amendment, supplement or waiver under this Section 9.02 may not (with respect to any Notes held by a non-consenting Holder):

(1) reduce a noteholder voting threshold for consent in this Indenture to an amendment, supplement or waiver;

 

131


(2) reduce the principal of or change the fixed maturity of any Note;

(3) alter or waive any provisions or redemption payment with respect to the redemption of the Notes (other than notice provisions);

(4) reduce the rate of or change the time for payment of interest on any Note;

(5) waive an Unmatured Event of Default or Event of Default in respect of the payment of principal of or premium, if any, or interest on the Notes (except a rescission of acceleration of the Notes by the Holders of more than 50% in aggregate principal amount of the then outstanding Notes and a waiver of the payment default that resulted from such acceleration);

(6) changes to the currency of the Notes;

(7) make any change in the provisions of this Indenture relating to waivers of past Unmatured Events of Default or the rights of Holders to receive payments of principal of or premium, if any, or interest on the Notes; and

(8) making any change in the preceding list of amendment and waiver provisions.

Section 9.03 Decisions under Other Finance Documents.

(a) Notwithstanding any provision of this Indenture or Section 7.2 of the CSAA to the contrary, the Trustee shall be required, without the requirement of any vote or consent by the Holders, with respect to any Covered Modification, to vote as follows:

(1) for any Covered Modification at a time when no Loans or Senior Debt Commitments in connection therewith remain outstanding, the Trustee shall vote in favor of such Covered Modification so long as such Covered Modification causes the provisions of the Finance Documents that are being amended to be equally or more restrictive on the Obligors than the covenants in this Indenture, in each case, as set forth in a certificate of an Authorized Officer of the Company or an Opinion of Counsel, upon which the Trustee may conclusively rely and will be fully protected in so relying;

(2) for any Covered Modification at a time when the Loans or Senior Debt Commitments in connection therewith then outstanding are less than 25% of the aggregate amount of Senior Debt then outstanding, the Trustee shall vote in conformity with the Credit Facility Lenders to the extent that any such Covered Modification causes the provisions of the Finance Documents that are being amended to be equally or more restrictive on the Obligors than the covenants in this Indenture, in each case, as set forth in a certificate of an Authorized Officer of the Company or an Opinion of Counsel, upon which the Trustee may conclusively rely and will be fully protected in so relying;

 

132


(3) for any Covered Modification at a time when the Loans or Senior Debt Commitments in connection therewith then outstanding are 25% or greater of the aggregate amount of Senior Debt then outstanding, the Trustee shall vote in conformity with the Intercreditor Agent, in each case, as set forth in a certificate of an Authorized Officer of the Company or an Opinion of Counsel, upon which the Trustee may conclusively rely and will be fully protected in so relying;

provided, however, that the Trustee shall vote as follows for certain modifications to the Finance Documents described below (“Fundamental Modifications”):

(4) if any Loans or Senior Debt Commitments in connection therewith remain outstanding, the Trustee shall vote in conformity with the Credit Facility Lenders with respect to Fundamental Modifications set forth in Sections 7.2(b)(ii)(A), 7.2(b)(ii)(B), 7.2(b)(ii)(C), and 7.2(b)(ii)(D) of the CSAA, or any other material modification to any Security Document, if the Fundamental Modification is not materially adverse to the Holders of the Notes, in each case, as set forth in a certificate from an Authorized Officer of the Company, upon which the Trustee may conclusively rely and will be fully protected in so relying, unless in any such case, such Fundamental Modification applies only to this Indenture;

(5) if any Loans or Senior Debt Commitments in connection therewith remain outstanding, the Trustee shall vote in conformity with the Term Lenders with respect to Fundamental Modifications set forth in Sections 7.2(a)(ii)(A), 7.2(a)(ii)(B) and 7.2(a)(ii)(C) of the CSAA, if the Fundamental Modification contemplated thereby (i) does not result in the Notes receiving payments that are less than pari passu with the Loans (other than due to timing differences in when payments are due on the Notes in accordance with their terms), and (ii) does not result in a material adverse change, when considered together with all other Fundamental Modifications to any particular item specified in this clause, to (x) the priority of the waterfall of payments under Section 4.7(a)(i)-(v) of the CSAA of any payment of principal, interest or other amounts payable (whether by prepayment or otherwise) under the Notes or (y) the then-required funding under then effective Finance Documents of the Additional Debt Service Reserve Account in respect of the Notes, in each case, as set forth in a certificate from an Authorized Officer of the Company, upon which the Trustee may conclusively rely and will be fully protected in so relying;

(6) for any Fundamental Modifications set forth in Sections 7.2(a)(ii)(D), 7.2(a)(ii)(E), 7.2(a)(ii)(F), 7.2(b)(ii)(E) or 7.2(c) of the CSAA, the Trustee shall vote at the direction of the Holders of the aggregate principal amount of the Notes as described in Article 9; and

(7) for any Fundamental Modifications made at a time when no Loans or Senior Debt Commitments in connection therewith remain outstanding, the Trustee shall vote at the direction of the aggregate principal amount of the Notes as set forth in Article 9.

 

133


Section 9.04 [Reserved].

Section 9.05 Revocation and Effect of Consents.

Until an amendment, supplement or waiver becomes effective, a consent to it by a Holder of a Note is a continuing consent by the Holder of a Note and every subsequent Holder of a Note or portion of a Note that evidences the same debt as the consenting Holder’s Note, even if notation of the consent is not made on any Note. However, any such Holder of a Note or subsequent Holder of a Note may revoke the consent as to its Note if the Trustee receives written notice of revocation before the date the amendment, supplement or waiver becomes effective. An amendment, supplement or waiver becomes effective in accordance with its terms and thereafter binds every Holder.

Section 9.06 Notation on or Exchange of Notes.

The Trustee may place an appropriate notation about an amendment, supplement or waiver on any Note thereafter authenticated. The Company in exchange for all Notes may issue and the Trustee shall, upon receipt of an Authentication Order, authenticate new Notes that reflect the amendment, supplement or waiver.

Failure to make the appropriate notation or issue a new Note will not affect the validity and effect of such amendment, supplement or waiver.

Section 9.07 Trustee to Sign Amendments, etc.

The Trustee will sign any amended or supplemental indenture authorized pursuant to this Article 9 if the amendment or supplement does not adversely affect the rights, duties, liabilities or immunities of the Trustee. The Company may not sign an amended or supplemental indenture until the Board of Directors (or the equivalent governing body) approves it. In executing any amended or supplemental indenture, the Trustee will be entitled to receive and (subject to Section 7.01) will be fully protected in relying upon an Officer’s Certificate and an Opinion of Counsel stating that the execution of such amended or supplemental indenture is authorized or permitted by this Indenture.

ARTICLE 10

COLLATERAL AND SECURITY

Section 10.01 Security.

(a) The payment of the Notes, when due, and the performance of all other Senior Debt are secured on a first-priority basis, subject only to Permitted Liens, by security interests in all Collateral owned or at any time acquired by the Company and the Guarantors.

(b) The Company shall, and shall cause each of the Guarantors to, do or cause to be done all acts and things which may be required, or which the Collateral Agent from time to time may reasonably request, to assure and confirm that the Collateral Agent holds, for the benefit of the Holders and the other Senior Debt, duly created, enforceable and perfected Liens upon the

 

134


Collateral as contemplated by this Indenture and the Senior Debt Instruments, so as to render the same available for the security and benefit of this Indenture and of the Notes, according to the intent and purposes hereof expressed subject in each case to any express provisions of any Senior Debt Instruments.

Section 10.02 Security Documents.

(a) The Notes, upon issuance and the execution and delivery of the Accession Agreement, will be Senior Debt for purposes of the CSAA and the Security Documents. The Trustee shall be the Senior Creditor Group Representative for the Notes. The Holders shall be Senior Noteholders.

(b) Upon the execution and delivery of the Senior Creditor Group Representative Accession Agreement (which document shall be substantially in the form attached as Schedule D- 1 to the CSAA (the “Accession Agreement”), each Holder of the Initial Notes, by its acceptance of the Initial Notes instructs and directs the Trustee to execute and deliver the Accession Agreement, to which the Trustee and the Collateral Agent will be a party on the Notes Issue Date, the Notes will constitute additional New Senior Debt (as defined in the Accession Agreement) and Senior Debt Obligations that is pari passu with all other Senior Debt Obligations and will be secured by the Collateral equally and ratable with the all other Senior Debt Obligations.

(c) Each Holder appoints the Trustee as Senior Creditor Group Representative of the Holders hereunder for purposes of the Accession Agreement and each Finance Document to which the Trustee is party on behalf of the Holders.

Section 10.03 Collateral.

(1) The Notes are secured, together with all other Senior Debt of the Company, equally and ratably by security interests granted to the Collateral Agent in all of the assets of the Company and the Guarantors.

Section 10.04 Release of Security Interests.

(a) With respect to the Notes or each series of Notes, the Collateral Agent’s Liens upon Collateral will no longer secure the obligations with respect to the Notes or that series of Notes and the right of the Holders of such obligations to the benefits and proceeds of the Collateral Agent’s Liens on Collateral will terminate and be discharged:

(1)

(A) upon satisfaction and discharge of this Indenture as set forth under in Section 12.01;

(B) upon a Legal Defeasance or Covenant Defeasance with respect to that series of Notes as set forth in Article 8; or

 

135


(C) upon payment in full in cash of the applicable Notes and all other related Note obligations that are outstanding, due and payable at the time the Notes are paid in full in cash; and

(2) in accordance with the CSAA.

Section 10.05 Release of Collateral.

(a) Notwithstanding any provision of this Indenture to the contrary, Collateral may only be released from the Lien and security interest created by the Security Documents at any time or from time to time in accordance with the provisions of the CSAA and the other Security Documents.

(b) No certificate shall be required in connection with any sale, transfer or other disposition of Collateral if such sale, transfer or other disposition does not constitute an Asset Sale or is otherwise expressly permitted by the terms of any Security Document and such Security Document does not require delivery of such certificate and no instrument of release or other action of the Collateral Agent is required in connection with such release.

(c) The release of any Collateral from the terms of this Indenture and the Security Documents will not be deemed to impair the security under this Indenture in contravention of the provisions hereof if and to the extent the Collateral is released pursuant to the terms of the Security Documents and none of the certificate delivery requirements under Article 10 shall affect or impair the ability of the Company to obtain the release of any Collateral to the extent the Company complies with its obligations to obtain such release under the CSAA and the other Security Documents.

Section 10.06 Termination of Security Interest.

Upon the payment in full of all obligations of the Company under this Indenture and the Notes, or upon Legal Defeasance, the Trustee will, at the request of the Company, deliver a certificate to the Collateral Agent stating that such obligations have been paid in full, and instruct the Collateral Agent to release the Liens pursuant to this Indenture and the Security Documents (subject to the satisfaction of any release of Lien provisions set forth in the Security Documents).

ARTICLE 11

NOTE GUARANTEES

Section 11.01 Note Guarantee.

(a) Subject to this Article 11 and to the requirements of Section 11 of the CSAA, each of the Guarantors hereby, jointly and severally, unconditionally reaffirms and confirms hereunder its guarantee made pursuant to Section 11 of the CSAA to the Collateral Agent for the ratable benefit of each of the Secured Parties, including each Holder of a Note authenticated and delivered by the Trustee, irrespective of the validity and enforceability of this Indenture, the Notes or the obligations of the Company hereunder or thereunder, pursuant to which it has guaranteed that:

(1) the principal of, premium and interest on, the Notes will be promptly paid in full when due, whether at maturity, by acceleration, redemption or otherwise, and interest on the overdue principal of and interest on the Notes, if any, if lawful, and all other obligations of the Company to the Holders or the Trustee hereunder or thereunder will be promptly paid in full or performed, all in accordance with the terms hereof and thereof; and

 

136


(2) in case of any extension of time of payment or renewal of any Notes or any of such other obligations, that same will be promptly paid in full when due or performed in accordance with the terms of the extension or renewal, whether at stated maturity, by acceleration or otherwise.

Failing payment when due of any amount so guaranteed or any performance so guaranteed for whatever reason, the Guarantors will be jointly and severally obligated to pay the same immediately, subject to the CSAA. Each Guarantor agrees that this is a guarantee of payment and not a guarantee of collection.

(b) The Guarantors hereby agree that their obligations under the Note Guarantees are unconditional, irrespective of the validity, regularity or enforceability of the Notes or this Indenture, the absence of any action to enforce the same, any waiver or consent by any Holder of the Notes with respect to any provisions hereof or thereof, the recovery of any judgment against the Company, any action to enforce the same or any other circumstance which might otherwise constitute a legal or equitable discharge or defense of a guarantor. To the extent permitted by applicable law, each Guarantor hereby waives diligence, presentment, demand of payment, filing of claims with a court in the event of insolvency or bankruptcy of the Company, any right to require a proceeding first against the Company, protest, notice and all demands whatsoever and covenant that this Note Guarantee will not be discharged except by complete performance of the obligations contained in the Notes and this Indenture.

(c) If any Holder or the Trustee is required by any court or otherwise to return to the Company, the Guarantors or any custodian, trustee, liquidator or other similar official acting in relation to either the Company or the Guarantors, any amount paid by either to the Trustee or such Holder, the Note Guarantee, to the extent theretofore discharged, will be reinstated in full force and effect.

(d) Each Guarantor agrees and confirms that the provisions of Section 11 of the CSAA apply to its Note Guarantees.

Section 11.02 Limitation on Guarantor Liability.

Each Guarantor, and by its acceptance of Notes, each Holder, hereby confirms that it is the intention of all such parties that the Note Guarantee of such Guarantor not constitute a fraudulent transfer or conveyance for purposes of Bankruptcy Law, the Uniform Fraudulent Conveyance Act, the Uniform Fraudulent Transfer Act or any similar federal or state law to the extent applicable to any Note Guarantee. To effectuate the foregoing intention, and to the extent permitted by applicable law, the Trustee, the Holders and the Guarantors hereby irrevocably agree that the obligations of such Guarantor will be limited to the maximum amount that will, after giving effect

 

137


to such maximum amount and all other contingent and fixed liabilities of such Guarantor that are relevant under such laws, and after giving effect to any collections from, rights to receive contribution from or payments made by or on behalf of any other Guarantor in respect of the obligations of such other Guarantor under this Article 11, result in the obligations of such Guarantor under its Note Guarantee not constituting a fraudulent transfer or conveyance.

Section 11.03 Execution and Delivery of Note Guarantee Notation.

To evidence its Note Guarantee set forth in Section 11.01, each Guarantor hereby agrees that a notation of such Note Guarantee substantially in the form attached as Exhibit D hereto or such other form as may be provided in any Supplemental Indenture will be endorsed by an Officer of such Guarantor on each Note authenticated and delivered by the Trustee and that this Indenture will be executed on behalf of such Guarantor by one of its Officers.

Each Guarantor hereby agrees that its Note Guarantee set forth in Section 11.01 will remain in full force and effect notwithstanding any failure to endorse on each Note a notation of such Note Guarantee.

If an Officer whose signature is on this Indenture or on the Note Guarantee no longer holds that office at the time the Trustee authenticates the Note on which a Note Guarantee is endorsed, the Note Guarantee will be valid nevertheless.

The delivery of any Note by the Trustee, after the authentication thereof hereunder, will constitute due delivery of the Note Guarantee set forth in this Indenture on behalf of the Guarantors.

In the event that the Company or any of its Restricted Subsidiaries creates or acquires any Domestic Subsidiary after the date of this Indenture, if required by Section 4.25, the Company will cause such Domestic Subsidiary to comply with the provisions of Section 4.25 and this Article 11, to the extent applicable.

Section 11.04 Guarantors May Consolidate, etc., on Certain Terms.

Except as otherwise provided in Section 11.05, the Company will not permit any Guarantor to dissolve or liquidate nor consolidate with or merge with or into another Person (whether or not such Guarantor is the surviving entity), convert into another form of entity, continue in another jurisdiction, or (except in connection with a Permitted Pipeline Sale) sell, assign, transfer, lease, convey or otherwise dispose of all or substantially all of its properties and assets, in one or more related transactions, to any Person (other than to or with or into the Company or another Guarantor) unless:

(a)

(1) the Person formed by or surviving such consolidation, merger, conversion or continuation (if other than the Guarantor) or to which such sale, assignment, transfer, lease, conveyance or disposition is made (the “Successor Guarantor”) is a Person (other than an individual) organized and existing under the same laws as the Guarantor was organized immediately prior to such transaction, or under the laws of the United States, any state of the United States or the District of Columbia;

 

138


(2) the Successor Guarantor, if other than such Guarantor, expressly assumes all the obligations of such Guarantor under this Indenture and the Security Documents and its Note Guarantee pursuant to a supplemental indenture, appropriate modifications (if necessary) to the Security Documents and Note Guarantee;

(3) no Event of Default or Unmatured Event of Default would exist immediately after giving effect to such transaction or series of related transactions; and

(4) the Company will have delivered to the Trustee a certificate from an Authorized Officer and an Opinion of Counsel, each stating that such consolidation or merger, conversion or continuation, or sale, assignment, transfer, lease, conveyance or disposition and such supplemental indenture and Security Documents and Note Guarantee, if any, comply with this Indenture and the Security Documents and that all conditions precedent provided for in this Indenture and the Security Documents relating to such transaction have been complied with; or

(b) the transaction does not violate the covenant described under Section 4.12.

In case of any such consolidation or merger, conversion or continuation, or sale, assignment, transfer, lease, conveyance or disposition and upon the assumption by the successor Person, by supplemental indenture, executed and delivered to the Trustee and satisfactory in form to the Trustee, of the Note Guarantee endorsed upon the Notes and the due and punctual performance of all of the covenants and conditions of this Indenture to be performed by the Guarantor, such successor Person will succeed to and be substituted for the Guarantor with the same effect as if it had been named herein as a Guarantor. Such successor Person thereupon may cause to be signed any or all of the Note Guarantees to be endorsed upon all of the Notes issuable hereunder which theretofore shall not have been signed by the Company and delivered to the Trustee. All the Note Guarantees so issued will in all respects have the same legal rank and benefit under this Indenture as the Note Guarantees theretofore and thereafter issued in accordance with the terms of this Indenture as though all of such Note Guarantees had been issued at the date of the execution hereof.

Except as set forth in Articles 4 and 5, nothing contained in this Indenture or in any of the Notes will prevent any consolidation or merger of a Guarantor with or into the Company or another Guarantor, or will prevent any sale or conveyance of the property of a Guarantor as an entirety or substantially as an entirety to the Company or another Guarantor.

 

139


Section 11.05 Releases.

The Note Guarantee of a Guarantor and the Security Interests granted by a Guarantor (and the Security Interests granted by the Company or TCP, as applicable, in respect of its ownership interests in a Guarantor or, as applicable, by the Pledgor in respect of its ownership interests in the Company or TCP) for the benefit of the Holders will be automatically and unconditionally released upon:

(a)

(1) any sale, exchange, disposition or transfer (by merger, consolidation or otherwise) made in compliance with the applicable provisions of this Indenture (including Section 4.12) to a Person that is not (either before or after giving effect to such transaction) the Company, TCP or a Restricted Subsidiary of either the Company or TCP of:

(A) all or substantially all of the Capital Stock of such Guarantor (and such Guarantor ceases to be a subsidiary of (x) in the case of any Guarantor other than TCP, the Company or TCP, as the case may be, or (y) in the case of TCP, the Pledgor, in each case, as a result of such sale, exchange, disposition or transfer); or

(B) all or substantially all of the assets of such Guarantor;

provided that, any such sale, exchange, disposition or transfer of all or substantially all of the Capital Stock of, or all or substantially all of the assets of, TCP may only occur if it is a Permitted Pipeline Sale; provided further that, if TCP is released as a Guarantor in accordance with the foregoing in connection with a Permitted Pipeline Sale, any Subsidiary of TCP that is a Guarantor shall also be released as a Guarantor and any Security Interests granted by such Subsidiary (and the Security Interests granted by TCP in respect of its ownership interests in such Subsidiary) shall also be released.

(2) designation of any Guarantor (other than TCP) as an Unrestricted Subsidiary in accordance with Section 4.40;

(3) exercise of Legal Defeasance or Covenant Defeasance, if any, pursuant to Article 8 or upon payment in full in cash of the applicable Notes and discharge of all other related Senior Debt Obligations that are outstanding, due and payable at the time the Notes are paid in full in cash and discharged;

(4) subject to the provisions described in Section 5.01, the merger or consolidation of any Guarantor with and into the Company, another Guarantor or a Person that will become a Guarantor substantially upon the consummation of such merger or consolidation, or upon the liquidation of such Guarantor following the transfer of all of its assets to the Company or another Guarantor;

(5) the Note Guarantees or Security Interests granted by the Company or any Guarantors being released and discharged pursuant to the CSAA, as described in the CSAA; or

(6) if otherwise permitted or required under the terms of this Indenture; and

(b) The Company delivering to the Trustee an Officer’s Certificate and Opinion of Counsel stating that all conditions precedent provided in this Indenture and the CSAA for the release of such Guarantor from its Note Guarantee or such Security Interests have been complied with.

 

140


If the requirements of clauses (a) and (b) above have been met, then upon request by the Company, the Trustee will (if required) execute an instrument evidencing the release of the Note Guarantee of such Guarantor and/or the applicable Security Interests.

Additionally, the Trustee will agree to release or assign the Note Guarantees held or made for the benefit of Holders on the date all outstanding amounts under the Notes have been redeemed, subject to reinstatement in the event any such payments are required to be returned.

ARTICLE 12

SATISFACTION AND DISCHARGE

Section 12.01 Satisfaction and Discharge.

This Indenture will be discharged and will cease to be of further effect as to all Notes, or all Notes of a series, issued hereunder, when:

(a) either:

(1) all Notes (or all Notes of such series, as applicable) that have been authenticated and delivered (except lost, stolen or destroyed Notes that have been replaced or paid and Notes for whose payment money has theretofore been deposited in trust or segregated and held in trust by the Company and thereafter repaid to the Company or discharged from such trust) have been delivered to the Trustee for cancellation; or

(2) all Notes (or all Notes of such series, as applicable) that have not been delivered to the Trustee for cancellation (A) have become due and payable or (B) will become due and payable within one year or are to be called for redemption within one year under irrevocable arrangements for the giving of notice of redemption by the Trustee in the name, and at the expense, of the Company, and the Company or any Guarantor has irrevocably deposited or caused to be deposited with the Trustee cash, U.S. government obligations or a combination thereof in an amount sufficient, without reinvestment, in the opinion of, or as certified by, a nationally recognized investment bank, appraisal firm, or firm of independent public accountants to pay and discharge the entire indebtedness on the Notes, not theretofore delivered to the Trustee for cancellation, for principal of, premium, if any, and interest to the stated maturity or redemption date;

(b) no Unmatured Event of Default or Event of Default has occurred and is Continuing on the date of such deposit (other than an Unmatured Event of Default or Event of Default resulting from the borrowing of funds to be applied to such deposit);

(c) the Company has paid or caused to be paid all other sums then due and payable under this Indenture by the Company;

(d) the Company has delivered irrevocable instructions to the Trustee under this Indenture to apply the deposited money toward the payment of the Notes (or Notes of such series, as applicable) at maturity or on the redemption date, as the case may be; and

 

141


(e) the Company has delivered to the Trustee an Officer’s Certificate and Opinion of Counsel to the effect that all conditions precedent under this Indenture relating to the discharge of the Notes (or Notes of such series, as applicable) have been complied with.

Section 12.02 Application of Trust Money.

Subject to the provisions of Section 8.06, all money deposited with the Trustee pursuant to Section 12.01 shall be held in trust and applied by it, in accordance with the provisions of the Notes and this Indenture, to the payment, either directly or through any Paying Agent (including the Company acting as its own Paying Agent) as the Trustee may determine, to the Persons entitled thereto, of the principal (and premium, if any) and interest for whose payment such money has been deposited with the Trustee; but such money need not be segregated from other funds except to the extent required by law.

If the Trustee or Paying Agent is unable to apply any money or Government Securities in accordance with Section 12.01 by reason of any legal proceeding or by reason of any order or judgment of any court or Governmental Authority enjoining, restraining or otherwise prohibiting such application, the Company’s and any Guarantor’s obligations under this Indenture and the Notes shall be revived and reinstated as though no deposit had occurred pursuant to Section 12.01; provided that if the Company has made any payment of principal of, premium or interest on, any Notes because of the reinstatement of its obligations, the Company shall be subrogated to the rights of the Holders of such Notes to receive such payment from the money or Government Securities held by the Trustee or Paying Agent.

ARTICLE 13

MISCELLANEOUS

Section 13.01 [Reserved].

Section 13.02 Notices.

Any notice or communication by the Company, any Guarantor or the Trustee to the others is duly given if in writing and delivered in Person or by first class mail (registered or certified, return receipt requested), facsimile transmission, electronic mail or overnight air courier guaranteeing next day delivery, to the others’ address:

If to the Company and/or any Guarantor:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Facsimile No.: [***]

E-mail: [***]

Attention: Chief Financial Officer

 

142


With a copy to (which copy shall be delivered as an accommodation and shall not be required to be delivered in satisfaction of any requirement hereof):

Latham & Watkins LLP

1271 Avenue of Americas

New York, NY 10020

Facsimile No.: [***]

E-mail: [***]

Attention: [***]

If to the Trustee:

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Facsimile No.: [***]

E-mail: [***]

Attention: Corporate Trust Administration

The Company, any Guarantor or the Trustee, by notice to the others, may designate additional or different addresses for subsequent notices or communications.

All notices and communications (other than those sent to Holders) will be deemed to have been duly given: at the time delivered by hand, if personally delivered; five Business Days after being deposited in the mail, postage prepaid, if mailed; when receipt acknowledged, if transmitted by facsimile; at the time sent, if transmitted by electronic mail; and the next Business Day after timely delivery to the courier, if sent by overnight air courier guaranteeing next day delivery; provided that all notices and communications to the Trustee shall not be deemed received by the Trustee unless actually received by the Trustee at its address, facsimile number or electronic mail address set forth above.

Any notice or communication to a Holder will be mailed by first class mail, or by certified or registered mail, return receipt requested, or by overnight air courier guaranteeing next day delivery to its address shown on the register kept by the Registrar. Failure to mail a notice or communication to a Holder or any defect in it will not affect its sufficiency with respect to other Holders.

If a notice or communication is mailed in the manner provided above within the time prescribed, it is duly given, whether or not the addressee receives it.

If the Company mails a notice or communication to Holders, it will send a copy to the Trustee and each Agent at the same time by any of the means described above with respect to notice or communication by the Company.

 

143


The Trustee shall have the right to accept and act upon instructions, including funds transfer instructions (“Instructions”) given pursuant to this Indenture and any other Transaction Document and delivered using Electronic Means; provided, however, that the Company and the Guarantors shall provide to the Trustee an incumbency certificate listing officers with the authority to provide such Instructions (“Instructing Officers”) and containing specimen signatures of such Instructing Officers, which incumbency certificate shall be amended by the Company and/or the Guarantors, as applicable, whenever a person is to be added or deleted from the listing. If the Company and/or the Guarantors, as applicable, elects to give the Trustee Instructions using Electronic Means and the Trustee in its discretion elects to act upon such Instructions, the Trustee’s understanding of such Instructions shall be deemed controlling. The Company and the Guarantors understand and agree that the Trustee cannot determine the identity of the actual sender of such Instructions and that the Trustee shall conclusively presume that directions that purport to have been sent by an Instructing Officer listed on the incumbency certificate provided to the Trustee have been sent by such Instructing Officer. The Company and the Guarantors shall be responsible for ensuring that only Instructing Officers transmit such Instructions to the Trustee and that the Company, the Guarantors and all Instructing Officers are solely responsible to safeguard the use and confidentiality of applicable user and authorization codes, passwords and/or authentication keys upon receipt by the Company and/or the Guarantors, as applicable. The Trustee shall not be liable for any losses, costs or expenses arising directly or indirectly from the Trustee’s reliance upon and compliance with such Instructions notwithstanding such directions conflict or are inconsistent with a subsequent written instruction. The Company and the Guarantors agree: (i) to assume all risks arising out of the use of Electronic Means to submit Instructions to the Trustee, including without limitation the risk of the Trustee acting on unauthorized Instructions, and the risk of interception and misuse by third parties; (ii) that it is fully informed of the protections and risks associated with the various methods of transmitting Instructions to the Trustee and that there may be more secure methods of transmitting Instructions than the method(s) selected by the Company and/or the Guarantors, as applicable; (iii) that the security procedures (if any) to be followed in connection with its transmission of Instructions provide to it a commercially reasonable degree of protection in light of its particular needs and circumstances; and (iv) to notify the Trustee immediately upon learning of any compromise or unauthorized use of the security procedures.

Section 13.03 [Reserved].

Section 13.04 Certificate and Opinion as to Conditions Precedent.

Upon any request or application by the Company to the Trustee to take any action under this Indenture, the Company shall furnish to the Trustee:

(a) an Officer’s Certificate in form reasonably satisfactory to the Trustee (which must include the statements set forth in Section 13.05) stating that, in the opinion of the signers, all conditions precedent and covenants, if any, provided for in this Indenture relating to the proposed action have been complied with; and

(b) an Opinion of Counsel in form reasonably satisfactory to the Trustee (which must include the statements set forth in Section 13.05) stating that, in the opinion of such counsel, all such conditions precedent and covenants have been complied with, provided, that no such Opinion of Counsel shall be delivered on the date of this Indenture in connection with the original issuance of the initial Global Notes.

 

144


Section 13.05 Statements Required in Certificate or Opinion.

Each certificate or opinion with respect to compliance with a condition or covenant provided for in this Indenture and must include:

(1) a statement that the Person making such certificate or opinion has read such covenant or condition;

(2) a brief statement as to the nature and scope of the examination or investigation upon which the statements or opinions contained in such certificate or opinion are based;

(3) a statement that, in the opinion of such Person, he or she has made such examination or investigation as is necessary to enable him or her to express an informed opinion as to whether or not such covenant or condition has been complied with; and

(4) a statement as to whether or not, in the opinion of such Person, such condition or covenant has been complied with.

Section 13.06 Rules by Trustee and Agents.

The Trustee may make reasonable rules for action by or at a meeting of Holders. The Registrar or Paying Agent may make reasonable rules and set reasonable requirements for its functions.

Section 13.07 No Personal Liability of Directors, Officers, Employees and Stockholders.

No past, present or future director, manager, officer, employee, incorporator, member, partner, Affiliate or stockholder of the Company or any Guarantor (in each case other than the Company and the Guarantors) or the Sponsor, as such, will have any liability for any obligations of the Company or the Guarantors under the Notes, this Indenture, the Note Guarantees, the Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

Section 13.08 Governing Law; Waiver of Jury Trial; Jurisdiction.

(a) THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THIS INDENTURE, THE NOTES AND THE NOTE GUARANTEES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

 

145


(b) Each of the Company, any Guarantors and the Trustee, and each Holder of a Note, by its acceptance thereof, hereby irrevocably waives, to the fullest extent permitted by applicable law, any and all right it may have to trial by jury in any legal proceeding directly or indirectly arising out of or relating to this Indenture, the securities or the transactions contemplated hereby or thereby.

(c) Each of the Company and each Guarantor, if any, irrevocably consents and submits, for itself and in respect of any of its assets or property, to the non-exclusive jurisdiction of any court of the State of New York or any United States federal court sitting, in each case, in the Borough of Manhattan, the City of New York, New York, United States of America, and any appellate court from any thereof in any suit, action or proceeding that may be brought in connection with this Indenture or the securities, and waives any immunity from the jurisdiction of such courts. Each of the Company and each Guarantor, if any, irrevocably waives, to the fullest extent permitted by law, any objection to any such suit, action or proceeding that may be brought in such courts whether on the grounds of venue, residence or domicile or on the ground that any such suit, action or proceeding has been brought in an inconvenient forum. Each of the Company and each Guarantor, if any, agrees, to the fullest extent that it lawfully may do so, that final judgment in any such suit, action or proceeding brought in such a court shall be conclusive and binding upon the Company and any Guarantor, if any, as applicable, and each of the Company and any Guarantor, if any, waives, to the fullest extent permitted by law, any objection to the enforcement by any competent court in the Company’s and the applicable Guarantor’s, as applicable, jurisdiction of organization of judgments validly obtained in any such court in New York on the basis of such suit, action or proceeding; provided, however, that neither the Company nor any Guarantor waive, and the foregoing provisions of this sentence shall not constitute or be deemed to constitute a waiver of, (i) any right to appeal any such judgment, to seek any stay or otherwise to seek reconsideration or review of any such judgment or (ii) any stay of execution or levy pending an appeal from, or a suit, action or proceeding for reconsideration of, any such judgment.

Section 13.09 No Adverse Interpretation of Other Agreements.

This Indenture may not be used to interpret any other indenture, loan or debt agreement of the Company or its Subsidiaries or of any other Person. Any such indenture, loan or debt agreement may not be used to interpret this Indenture.

Section 13.10 Successors.

All agreements of the Company in this Indenture and the Notes will bind its successors. All agreements of the Trustee in this Indenture will bind its successors. All agreements of each Guarantor in this Indenture will bind its successors, except as otherwise provided in Section 11.05.

Section 13.11 Severability.

In case any provision in this Indenture or in the Notes is invalid, illegal or unenforceable, the validity, legality and enforceability of the remaining provisions will not in any way be affected or impaired thereby.

 

146


Section 13.12 Execution; Counterpart Originals.

The parties may manually or electronically sign any number of copies of this Indenture. Each signed copy will be an original, but all of them together represent the same agreement. The exchange of copies of this Indenture and of signature pages by facsimile or electronic format (i.e., “pdf” or “tif”) transmission shall constitute effective execution and delivery of this Indenture as to the parties hereto and may be used in lieu of the original Indenture for all purposes. Signatures of the parties hereto transmitted by facsimile or electronic format (i.e., “pdf” or “tif”) shall be deemed to be their original signatures for all purposes. Delivery of an executed Indenture by one party to any other party may be made by facsimile, electronic mail (including any electronic signature complying with the New York Electronic Signatures and Records Act (N.Y. State Tech. §§ 301- 309), as amended from time to time, or other applicable law), including DocuSign, or other transmission method, and the parties hereto agree that any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

Section 13.13 Trustee’s Receipt of Funds to the Extent not Required to be Applied to Payment of the Notes.

To the extent the Trustee receives any money from the Company or pursuant to any of the Finance Documents, and such money is not required to be used to redeem or repay the Notes as set forth in a certificate of an Authorized Officer of the Company, such moneys shall be deposited into the Account as specified by the Company in such certificate.

Section 13.14 Table of Contents, Headings, etc.

The Table of Contents, Cross-Reference Table and Headings of the Articles and Sections of this Indenture have been inserted for convenience of reference only, are not to be considered a part of this Indenture and will in no way modify or restrict any of the terms or provisions hereof.

[Signatures on following page]

 

147


SIGNATURES

Dated as of August 5, 2021

 

VENTURE GLOBAL CALCASIEU PASS, LLC
By:   /s/ Leah Woodward
Name:   Leah Woodward
Title:   Treasurer
TRANSCAMERON PIPELINE, LLC
By:   /s/ Leah Woodward
Name:   Leah Woodward
Title:   Treasurer
THE BANK OF NEW YORK MELLON,
TRUST COMPANY, N.A., as Trustee
By:   /s/ Lawrence M. Kusch
Name:   Lawrence M. Kusch
Title:   Vice President

[Signature Page to Indenture]


EXHIBIT A-1

[Face of Note]

CUSIP: 92328M AA1

ISIN: US92328MAA18

3.875% Senior Secured Notes due 2029

No. _____ $ _________

VENTURE GLOBAL CALCASIEU PASS, LLC

promises to pay to ________ or registered assigns, the principal sum of ___________________________________________ DOLLARS on August 15, 2029.

Interest Payment Dates: February 15 and August 15, commencing February 15, 2022

Record Dates: February 1 and August 1

Dated: ____________, 20 ____

 

VENTURE GLOBAL CALCASIEU PASS, LLC

By:

   

Name:

Title:

 

This is one of the Notes referred to in the within-mentioned Indenture:
THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee
By:                 
     Authorized Signatory
Dated: ____________, 20     

 

A-1-1


[Back of Note]

3.875% Senior Secured Notes due 2029

[Insert the Global Note Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Private Placement Legend, if applicable pursuant to the provisions of the Indenture]

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Company”), promises to pay interest on the principal amount of this Note at 3.875% per annum from August 5, 2021 until maturity. The Company will pay interest semi-annually in arrears on February 15 and August 15 of each year, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from the date of issuance; provided that if there is no existing Unmatured Event of Default or Event of Default in the payment of interest, and if this Note is authenticated between a record date referred to on the face hereof and the next succeeding Interest Payment Date, interest shall accrue from such next succeeding Interest Payment Date; provided further that the first Interest Payment Date shall be February 15, 2022. The Company will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue principal and premium, if any, from time to time on demand at a rate that is 0.50% per annum in excess of the rate then in effect to the extent lawful; it will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue installments of interest (without regard to any applicable grace periods) from time to time on demand at the rate equal to 0.50% per annum in excess of the then applicable interest rate on the Notes of such series to the extent lawful. Interest will be computed on the basis of a 360-day year of twelve 30-day months.

(2) METHOD OF PAYMENT. The Company will pay interest on the Notes (except defaulted interest) to the Persons who are registered Holders of Notes at the close of business on the February 1 or August 1 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium and interest at the office or agency of the Paying Agent or Registrar maintained for such purpose within or without the City and State of New York, or, at the option of the Company, payment of interest may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that payment by wire transfer of immediately available funds will be required with respect to principal of and interest, premium on, all Global Notes and all other Notes the Holders of which will have provided wire transfer instructions to the Company or the Paying Agent. Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

 

A-1-2


(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Company may change any Paying Agent or Registrar without notice to any Holder. The Company or any of its Subsidiaries may act in any such capacity.

(4) INDENTURE AND SECURITY DOCUMENTS. The Company issued the Notes under an Indenture dated as of August 5, 2021 (the “Indenture”) among the Company, TCP and the Trustee. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are secured obligations of the Company. The Notes are secured by a pledge of Collateral (as defined in the Indenture) pursuant to the Security Documents referred to in the Indenture. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

At any time or from time to time prior to February 15, 2029 (the “2029 Call Date”), the Company may, at its option, redeem all or a part of the 2029 Notes at a redemption price equal to the 2029 Make-Whole Price plus accrued and unpaid interest on such 2029 Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

2029 Make-Whole Price” with respect to any 2029 Notes to be redeemed, means an amount equal to the greater of:

(1) 100% of the principal amount of such 2029 Notes, without any premium, penalty or charge; and

(2) an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2029 Call Date (assuming the principal amount is scheduled to be paid on the 2029 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate (as defined below) plus 50 basis points.

At any time on or after the 2029 Call Date, the Company may, at its option, redeem all or a part of the 2029 Notes, at a redemption price equal to 100% of the principal amount of the 2029 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

Treasury Rate” means the yield to maturity at the time of computation of United States Treasury securities with a constant maturity (as compiled and published in the most recent Federal Reserve Statistical Release H.15 (519) which has become publicly available at least two Business Days (but not more than five Business Days) prior to the relevant redemption date (or, if such Statistical Release is not so published or available, any publicly available source of similar market

 

A-1-3


data selected by the Company in good faith)) most nearly equal to the period from the redemption date to the 2029 Call Date on which the principal of the 2029 Notes being redeemed will be paid in full; provided, however, that if the period from the redemption date to such 2029 Call Date is not equal to the constant maturity of a United States Treasury security for which a weekly average yield is given, the Treasury Rate shall be obtained by linear interpolation (calculated to the nearest one-twelfth of a year) from the weekly average yields of United States Treasury securities for which such yields are given, except that if the period from the redemption date to such 2029 Call Date is less than one year, the weekly average yield on actually traded United States Treasury securities adjusted to a constant maturity of one year shall be used.

The notice of redemption with respect to the foregoing redemption need not set forth the 2029 Make-Whole Price, but only the manner of calculation thereof. The Company will determine the redemption price (including any 2029 Make-Whole Price) and will notify the Trustee of the redemption price (including any 2029 Make-Whole Price) with respect to any redemption promptly, and the Trustee shall not be responsible for such calculation or determination.

(6) MANDATORY REDEMPTION.

The Company is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control, the Company will make an offer (a “Change of Control Offer”) of payment (a “Change of Control Payment”) to each Holder to repurchase all or any part (equal to $2,000 and integral multiples of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash equal to not less than 101% of the aggregate principal amount of Notes repurchased plus accrued and unpaid interest if any, to the date of repurchase (the “Change of Control Payment Date,” which date will be no earlier than the date of the corresponding Change of Control). No later than 30 days following any Change of Control, the Company will deliver a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Company will be required to make an Asset Sale Offer, Excess Loss Proceeds Offer, PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer to the extent provided in Sections 4.12, 4.19, 4.20 and 4.21, respectively, of the Indenture.

(8) NOTICE OF REDEMPTION. Notice of redemption will be mailed at least 10 days but not more than 60 days before the redemption date to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes of a series or a satisfaction or discharge of the Indenture. Notes in denominations larger than $2,000 may be redeemed in part but only in whole multiples of $1,000 in excess thereof, unless all of the Notes held by a Holder are to be redeemed.

 

A-1-4


(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form without coupons in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Company may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Company need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Company need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the corresponding Interest Payment Date.

(10) PERSONS DEEMED OWNERS. The registered Holder of a Note may be treated as its owner for all purposes.

(11) TRUSTEE DEALINGS WITH COMPANY. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Company or its Affiliates, and may otherwise deal with the Company or its Affiliates, as if it were not the Trustee.

(12) NO RECOURSE AGAINST OTHERS.

No past, present or future director, manager, officer, employee, incorporator, member, partner, Affiliate or stockholder of the Company or any Guarantor (in each case other than the Company and the Guarantors) or the Sponsor, as such, will have any liability for any obligations of the Company or the Guarantors under the Notes, this Indenture, the Note Guarantees, the Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(13) AUTHENTICATION. This Note will not be valid until authenticated by the manual or electronic signature of the Trustee or an authenticating agent.

(14) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(15) CUSIP NUMBERS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Company has caused CUSIP numbers to be printed on the Notes, and the Trustee may use CUSIP numbers in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

 

A-1-5


(16) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THIS NOTE AND THE NOTE GUARANTEES.

The Company will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Facsimile No.: [***]

Attention: Treasurer

 

A-1-6


ASSIGNMENT FORM

To assign this Note, fill in the form below:

 

(I) or (we) assign and transfer this Note to:     
   (Insert assignee’s legal name)

 

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

 

 

 

 

(Print or type assignee’s name, address and zip code)

and irrevocably                                           appoint to transfer this Note on the books of the Company. The agent may substitute another to act for him.

Date:       

 

Your Signature:    
  (Sign exactly as your name appears on the face of this Note)

Signature Guarantee*:                

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A-1-7


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, check the appropriate box below:

 

☐ Section 4.12

  

☐ Section 4.17

  

☐ Section 4.19

  

☐ Section 4.20

☐ Section 4.21

        

If you want to elect to have only part of the Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, state the amount you elect to have purchased:

$      

Date:      

 

Your Signature:    
  (Sign exactly as your name appears on the face of this Note)

Tax Identification No:

   

Signature Guarantee*:             

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A-1-8


SCHEDULE OF EXCHANGES OF INTERESTS IN THE GLOBAL NOTE

The following exchanges of a part of this Global Note for an interest in another Global Note or for a Definitive Note, or exchanges of a part of another Global Note or Definitive Note for an interest in this Global Note, have been made:

 

Date of

Exchange

 

Amount of

decrease in

Principal

Amount [at

maturity] of

this Global

Note

 

Amount of

increase in

Principal

Amount [at

maturity] of

this Global

Note

  

Principal

Amount [at

maturity] of

this Global

Note following

such decrease

(or increase)

  

Signature of

authorized

signatory of

Trustee or

Custodian

 

A-1-9


EXHIBIT A-2

[Face of Regulation S Temporary Global Note]

CUSIP: U9220M AA1

ISIN: USU9220MAA19

3.875% Senior Secured Notes due 2029

 

No.       $        

VENTURE GLOBAL CALCASIEU PASS, LLC

promises to pay to        or registered assigns, the principal sum of                       DOLLARS on August 15, 2029.

Interest Payment Dates: February 15 and August 15, commencing February 15, 2022

Record Dates: February 1 and August 1

Dated:      , 20

 

VENTURE GLOBAL CALCASIEU PASS, LLC
By:    
Name:  
Title:  

 

This is one of the Notes referred to

in the within-mentioned Indenture:

  

THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A.,
as Trustee

  

 

By:    
  Authorized Signatory
Dated:     , 20

 

A-2-1


[Back of Regulation S Temporary Global Note]

3.875% Senior Secured Notes due 2029

THE RIGHTS ATTACHING TO THIS REGULATION S TEMPORARY GLOBAL NOTE, AND THE CONDITIONS AND PROCEDURES GOVERNING ITS EXCHANGE FOR CERTIFICATED NOTES, ARE AS SPECIFIED IN THE INDENTURE (AS DEFINED HEREIN). NEITHER THE HOLDER NOR THE BENEFICIAL OWNERS OF THIS REGULATION S TEMPORARY GLOBAL NOTE SHALL BE ENTITLED TO RECEIVE PAYMENT OF INTEREST HEREON.

THIS GLOBAL NOTE IS HELD BY THE DEPOSITARY (AS DEFINED IN THE INDENTURE GOVERNING THIS NOTE) OR ITS NOMINEE IN CUSTODY FOR THE BENEFIT OF THE BENEFICIAL OWNERS HEREOF, AND IS NOT TRANSFERABLE TO ANY PERSON UNDER ANY CIRCUMSTANCES EXCEPT THAT (1) THE TRUSTEE MAY MAKE SUCH NOTATIONS HEREON AS MAY BE REQUIRED PURSUANT TO SECTION 2.06 OF THE INDENTURE, (2) THIS GLOBAL NOTE MAY BE EXCHANGED IN WHOLE BUT NOT IN PART PURSUANT TO SECTION 2.06(a) OF THE INDENTURE, (3) THIS GLOBAL NOTE MAY BE DELIVERED TO THE TRUSTEE FOR CANCELLATION PURSUANT TO SECTION 2.11 OF THE INDENTURE AND (4) THIS GLOBAL NOTE MAY BE TRANSFERRED TO A SUCCESSOR DEPOSITARY WITH THE PRIOR WRITTEN CONSENT OF THE COMPANY.

UNLESS AND UNTIL IT IS EXCHANGED IN WHOLE OR IN PART FOR NOTES IN DEFINITIVE FORM, THIS NOTE MAY NOT BE TRANSFERRED EXCEPT AS A WHOLE BY THE DEPOSITARY TO A NOMINEE OF THE DEPOSITARY OR BY A NOMINEE OF THE DEPOSITARY TO THE DEPOSITARY OR ANOTHER NOMINEE OF THE DEPOSITARY OR BY THE DEPOSITARY OR ANY SUCH NOMINEE TO A SUCCESSOR DEPOSITARY OR A NOMINEE OF SUCH SUCCESSOR DEPOSITARY. UNLESS THIS CERTIFICATE IS PRESENTED BY AN AUTHORIZED REPRESENTATIVE OF THE DEPOSITORY TRUST COMPANY (55 WATER STREET, NEW YORK, NEW YORK) (“DTC”), TO THE COMPANY OR ITS AGENT FOR REGISTRATION OF TRANSFER, EXCHANGE OR PAYMENT, AND ANY CERTIFICATE ISSUED IS REGISTERED IN THE NAME OF CEDE & CO. OR SUCH OTHER NAME AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC (AND ANY PAYMENT IS MADE TO CEDE & CO. OR SUCH OTHER ENTITY AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC), ANY TRANSFER, PLEDGE OR OTHER USE HEREOF FOR VALUE OR OTHERWISE BY OR TO ANY PERSON IS WRONGFUL INASMUCH AS THE REGISTERED OWNER HEREOF, CEDE & CO., HAS AN INTEREST HEREIN.

THIS NOTE HAS NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), AND MAY NOT BE OFFERED, SOLD, PLEDGED OR OTHERWISE TRANSFERRED EXCEPT IN ACCORDANCE WITH THE FOLLOWING SENTENCE. BY ITS ACQUISITION HEREOF OR OF A BENEFICIAL INTEREST HEREIN, THE ACQUIRER AGREES FOR THE BENEFIT OF VENTURE GLOBAL CALCASIEU PASS, LLC THAT IT WILL NOT OFFER, SELL, PLEDGE OR OTHERWISE TRANSFER THIS NOTE OR ANY BENEFICIAL INTEREST HEREIN, EXCEPT IN ACCORDANCE WITH THE SECURITIES ACT AND ANY APPLICABLE SECURITIES LAWS OF ANY

 

A-2-2


STATE OF THE UNITED STATES AND ONLY (A) TO VENTURE GLOBAL CALCASIEU PASS, LLC, (B) PURSUANT TO A REGISTRATION STATEMENT WHICH HAS BECOME EFFECTIVE UNDER THE SECURITIES ACT, (C) TO A QUALIFIED INSTITUTIONAL BUYER IN COMPLIANCE WITH RULE 144A UNDER THE SECURITIES ACT, (D) IN AN OFFSHORE TRANSACTION IN COMPLIANCE WITH RULE 904 OF REGULATION S UNDER THE SECURITIES ACT, (E) TO AN INSTITUTIONAL “ ACCREDITED INVESTOR” WITHIN THE MEANING OF RULE 501(a)(1), (2), (3) OR (7) UNDER THE SECURITIES ACT THAT IS NOT A QUALIFIED INSTITUTIONAL BUYER AND THAT IS PURCHASING FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF ANOTHER INSTITUTIONAL ACCREDITED INVESTOR, IN EACH CASE IN A MINIMUM PRINCIPAL AMOUNT OF THE SECURITIES OF $250,000, FOR INVESTMENT PURPOSES AND NOT WITH A VIEW TO OR FOR OFFER OR SALE IN CONNECTION WITH ANY DISTRIBUTION IN VIOLATION OF THE SECURITIES ACT OR (F) PURSUANT TO AN EXEMPTION FROM REGISTRATION PROVIDED BY RULE 144 UNDER THE SECURITIES ACT OR ANY OTHER AVAILABLE EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT. PRIOR TO THE REGISTRATION OF ANY TRANSFER IN ACCORDANCE WITH CLAUSES (C), (D) OR (E) ABOVE, A DULY COMPLETED AND SIGNED CERTIFICATE (THE FORM OF WHICH MAY BE OBTAINED FROM THE TRUSTEE) MUST BE DELIVERED TO THE TRUSTEE. PRIOR TO THE REGISTRATION OF ANY TRANSFER IN ACCORDANCE WITH (F) ABOVE, VENTURE GLOBAL CALCASIEU PASS, LLC RESERVES THE RIGHT TO REQUIRE THE DELIVERY OF SUCH LEGAL OPINIONS, CERTIFICATIONS OR OTHER EVIDENCE AS MAY REASONABLY BE REQUIRED IN ORDER TO DETERMINE THAT THE PROPOSED TRANSFER IS BEING MADE IN COMPLIANCE WITH THE SECURITIES ACT AND APPLICABLE STATE SECURITIES LAWS. NO REPRESENTATION IS MADE AS TO THE AVAILABILITY OF ANY RULE 144 EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT.

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Company”), promises to pay interest on the principal amount of this Note at 3.875% per annum from August 5, 2021 until maturity. The Company will pay interest semi-annually in arrears on February 15 and August 15 of each year, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from the date of issuance; provided that if there is no existing Unmatured Event of Default or Event of Default in the payment of interest, and if this Note is authenticated between a record date referred to on the face hereof and the next succeeding Interest Payment Date, interest shall accrue from such next succeeding Interest Payment Date; provided further that the first Interest Payment Date shall be February 15, 2022. The Company will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue principal and premium, if any, from time to time on demand at a rate that is 0.50% per annum in excess of the rate then in effect to the extent lawful; it will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue installments of interest (without regard to any applicable grace periods) from time to time on demand at the rate equal to 0.50% per annum in excess of the then applicable interest rate on the Notes of such series to the extent lawful. Interest will be computed on the basis of a 360-day year of twelve 30-day months.

 

A-2-3


Until this Regulation S Temporary Global Note is exchanged for one or more Regulation S Permanent Global Notes, the Holder hereof shall not be entitled to receive payments of interest hereon; until so exchanged in full, this Regulation S Temporary Global Note shall in all other respects be entitled to the same benefits as other Notes under the Indenture.

(2) METHOD OF PAYMENT. The Company will pay interest on the Notes (except defaulted interest) to the Persons who are registered Holders of Notes at the close of business on the February 1 or August 1 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium and interest at the office or agency of the Paying Agent or Registrar maintained for such purpose within or without the City and State of New York, or, at the option of the Company, payment of interest may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that payment by wire transfer of immediately available funds will be required with respect to principal of and interest, premium on, all Global Notes and all other Notes the Holders of which will have provided wire transfer instructions to the Company or the Paying Agent. Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Company may change any Paying Agent or Registrar without notice to any Holder. The Company or any of its Subsidiaries may act in any such capacity.

(4) INDENTURE AND SECURITY DOCUMENTS. The Company issued the Notes under an Indenture dated as of August 5, 2021 (the “Indenture”) among the Company, TCP and the Trustee. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are secured obligations of the Company. The Notes are secured by a pledge of Collateral (as defined in the Indenture) pursuant to the Security Documents referred to in the Indenture. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

At any time or from time to time prior to February 15, 2029 (the “2029 Call Date”), the Company may, at its option, redeem all or a part of the 2029 Notes at a redemption price equal to the 2029 Make-Whole Price plus accrued and unpaid interest on such 2029 Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

 

A-2-4


2029 Make-Whole Price” with respect to any 2029 Notes to be redeemed, means an amount equal to the greater of:

(1) 100% of the principal amount of such 2029 Notes, without any premium, penalty or charge; and

(2) an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2029 Call Date (assuming the principal amount is scheduled to be paid on the 2029 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate (as defined below) plus 50 basis points.

At any time on or after the 2029 Call Date, the Company may, at its option, redeem all or a part of the 2029 Notes, at a redemption price equal to 100% of the principal amount of the 2029 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

Treasury Rate” means the yield to maturity at the time of computation of United States Treasury securities with a constant maturity (as compiled and published in the most recent Federal Reserve Statistical Release H.15 (519) which has become publicly available at least two Business Days (but not more than five Business Days) prior to the relevant redemption date (or, if such Statistical Release is not so published or available, any publicly available source of similar market data selected by the Company in good faith)) most nearly equal to the period from the redemption date to the 2029 Call Date on which the principal of the 2029 Notes being redeemed will be paid in full; provided, however, that if the period from the redemption date to such 2029 Call Date is not equal to the constant maturity of a United States Treasury security for which a weekly average yield is given, the Treasury Rate shall be obtained by linear interpolation (calculated to the nearest one-twelfth of a year) from the weekly average yields of United States Treasury securities for which such yields are given, except that if the period from the redemption date to such 2029 Call Date is less than one year, the weekly average yield on actually traded United States Treasury securities adjusted to a constant maturity of one year shall be used.

The notice of redemption with respect to the foregoing redemption need not set forth the 2029 Make-Whole Price, but only the manner of calculation thereof. The Company will determine the redemption price (including any 2029 Make-Whole Price) and will notify the Trustee of the redemption price (including any 2029 Make-Whole Price) with respect to any redemption promptly, and the Trustee shall not be responsible for such calculation or determination.

 

A-2-5


(6) MANDATORY REDEMPTION.

The Company is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control, the Company will make an offer (a “Change of Control Offer”) of payment (a “Change of Control Payment”) to each Holder to repurchase all or any part (equal to $2,000 and integral multiples of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash equal to not less than 101% of the aggregate principal amount of Notes repurchased plus accrued and unpaid interest if any, to the date of repurchase (the “Change of Control Payment Date,” which date will be no earlier than the date of the corresponding Change of Control). No later than 30 days following any Change of Control, the Company will deliver a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Company will be required to make an Asset Sale Offer, Excess Loss Proceeds Offer, PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer to the extent provided in Sections 4.12, 4.19, 4.20 and 4.21, respectively, of the Indenture.

(8) NOTICE OF REDEMPTION. Notice of redemption will be mailed at least 10 days but not more than 60 days before the redemption date to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes of a series or a satisfaction or discharge of the Indenture. Notes in denominations larger than $2,000 may be redeemed in part but only in whole multiples of $1,000 in excess thereof, unless all of the Notes held by a Holder are to be redeemed.

(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form without coupons in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Company may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Company need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Company need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the corresponding Interest Payment Date.

(10) PERSONS DEEMED OWNERS. The registered Holder of a Note may be treated as its owner for all purposes.

(11) TRUSTEE DEALINGS WITH COMPANY. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Company or its Affiliates, and may otherwise deal with the Company or its Affiliates, as if it were not the Trustee.

 

A-2-6


(12) NO RECOURSE AGAINST OTHERS.

No past, present or future director, manager, officer, employee, incorporator, member, partner, Affiliate or stockholder of the Company or any Guarantor (in each case other than the Company and the Guarantors) or the Sponsor, as such, will have any liability for any obligations of the Company or the Guarantors under the Notes, this Indenture, the Note Guarantees, the Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(13) AUTHENTICATION. This Note will not be valid until authenticated by the manual or electronic signature of the Trustee or an authenticating agent.

(14) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(15) CUSIP NUMBERS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Company has caused CUSIP numbers to be printed on the Notes, and the Trustee may use CUSIP numbers in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

(16) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THIS NOTE AND THE NOTE GUARANTEES.

The Company will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Facsimile No.: [***]

Attention: Treasurer

 

A-2-7


ASSIGNMENT FORM

To assign this Note, fill in the form below:

 

(I) or (we) assign and transfer this Note to:     
   (Insert assignee’s legal name)

 

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

 

 

 

 

(Print or type assignee’s name, address and zip code)

and irrevocably                                           appoint to transfer this Note on the books of the Company. The agent may substitute another to act for him.

Date:       

 

Your Signature:    
  (Sign exactly as your name appears on the face of this Note)

Signature Guarantee*:                

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A-2-8


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, check the appropriate box below:

 

☐ Section 4.12

  

☐ Section 4.17

  

☐ Section 4.19

  

☐ Section 4.20

☐ Section 4.21

        

If you want to elect to have only part of the Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, state the amount you elect to have purchased:

$      

Date:      

 

Your Signature:    
  (Sign exactly as your name appears on the face of this Note)

Tax Identification No:

   

Signature Guarantee*:             

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A-2-9


SCHEDULE OF EXCHANGES OF INTERESTS IN THE REGULATION S

TEMPORARY GLOBAL NOTE

The following exchanges of a part of this Regulation S Temporary Global Note for an interest in another Global Note, or exchanges of a part of another other Restricted Global Note or for an interest in this Regulation S Temporary Global Note, have been made:

 

Date of

Exchange

 

Amount of

decrease in

Principal

Amount [at

maturity] of

this Global

Note

 

Amount of

increase in

Principal

Amount [at

maturity] of

this Global

Note

  

Principal

Amount [at

maturity] of

this Global

Note following

such decrease

(or increase)

  

Signature of

authorized

signatory of

Trustee or

Custodian

 

A-2-10


EXHIBIT A-3

[Face of Note]

CUSIP: 92328M AB9

ISIN: US92328MAB90

4.125% Senior Secured Notes due 2031

 

No.       $        

VENTURE GLOBAL CALCASIEU PASS, LLC

promises to pay to        or registered assigns, the principal sum of                       DOLLARS on August 15, 2031.

Interest Payment Dates: February 15 and August 15, commencing February 15, 2022

Record Dates: February 1 and August 1

Dated:      , 20

 

VENTURE GLOBAL CALCASIEU PASS, LLC
By:    
Name:  
Title:  

 

This is one of the Notes referred to

in the within-mentioned Indenture:

  

THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A.,
as Trustee

  

 

By:    
  Authorized Signatory
Dated:     , 20

 

A-3-1


[Back of Note]

4.125% Senior Secured Notes due 2031

[Insert the Global Note Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Private Placement Legend, if applicable pursuant to the provisions of the Indenture]

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Company”), promises to pay interest on the principal amount of this Note at 4.125% per annum from August 5, 2021 until maturity. The Company will pay interest semi-annually in arrears on February 15 and August 15 of each year, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from the date of issuance; provided that if there is no existing Unmatured Event of Default or Event of Default in the payment of interest, and if this Note is authenticated between a record date referred to on the face hereof and the next succeeding Interest Payment Date, interest shall accrue from such next succeeding Interest Payment Date; provided further that the first Interest Payment Date shall be February 15, 2022. The Company will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue principal and premium, if any, from time to time on demand at a rate that is 0.50% per annum in excess of the rate then in effect to the extent lawful; it will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue installments of interest (without regard to any applicable grace periods) from time to time on demand at the rate equal to 0.50% per annum in excess of the then applicable interest rate on the Notes of such series to the extent lawful. Interest will be computed on the basis of a 360-day year of twelve 30-day months.

(2) METHOD OF PAYMENT. The Company will pay interest on the Notes (except defaulted interest) to the Persons who are registered Holders of Notes at the close of business on the February 1 or August 1 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium and interest at the office or agency of the Paying Agent or Registrar maintained for such purpose within or without the City and State of New York, or, at the option of the Company, payment of interest may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that payment by wire transfer of immediately available funds will be required with respect to principal of and interest, premium on, all Global Notes and all other Notes the Holders of which will have provided wire transfer instructions to the Company or the Paying Agent. Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

 

A-3-2


(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Company may change any Paying Agent or Registrar without notice to any Holder. The Company or any of its Subsidiaries may act in any such capacity.

(4) INDENTURE AND SECURITY DOCUMENTS. The Company issued the Notes under an Indenture dated as of August 5, 2021 (the “Indenture”) among the Company, TCP and the Trustee. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are secured obligations of the Company. The Notes are secured by a pledge of Collateral (as defined in the Indenture) pursuant to the Security Documents referred to in the Indenture. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

At any time or from time to time prior to February 15, 2031 (the “2031 Call Date”), the Company may, at its option, redeem all or a part of the 2031 Notes at a redemption price equal to the 2031 Make-Whole Price plus accrued and unpaid interest on such 2031 Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

2031 Make-Whole Price” with respect to any 2031 Notes to be redeemed, means an amount equal to the greater of:

(1) 100% of the principal amount of such 2031 Notes, without any premium, penalty or charge; and

(2) an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2031 Call Date (assuming the principal amount is scheduled to be paid on the 2031 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate (as defined below) plus 50 basis points.

At any time on or after the 2031 Call Date, the Company may, at its option, redeem all or a part of the 2031 Notes, at a redemption price equal to 100% of the principal amount of the 2031 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

Treasury Rate” means the yield to maturity at the time of computation of United States Treasury securities with a constant maturity (as compiled and published in the most recent Federal Reserve Statistical Release H.15 (519) which has become publicly available at least two Business Days (but not more than five Business Days) prior to the relevant redemption date (or, if such Statistical Release is not so published or available, any publicly available source of similar market

 

A-3-3


data selected by the Company in good faith)) most nearly equal to the period from the redemption date to the 2031 Call Date on which the principal of the 2031 Notes being redeemed will be paid in full; provided, however, that if the period from the redemption date to such 2031 Call Date is not equal to the constant maturity of a United States Treasury security for which a weekly average yield is given, the Treasury Rate shall be obtained by linear interpolation (calculated to the nearest one-twelfth of a year) from the weekly average yields of United States Treasury securities for which such yields are given, except that if the period from the redemption date to such 2031 Call Date is less than one year, the weekly average yield on actually traded United States Treasury securities adjusted to a constant maturity of one year shall be used.

The notice of redemption with respect to the foregoing redemption need not set forth the 2031 Make-Whole Price, but only the manner of calculation thereof. The Company will determine the redemption price (including any 2031 Make-Whole Price) and will notify the Trustee of the redemption price (including any 2031 Make-Whole Price) with respect to any redemption promptly, and the Trustee shall not be responsible for such calculation or determination.

(6) MANDATORY REDEMPTION.

The Company is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control, the Company will make an offer (a “Change of Control Offer”) of payment (a “Change of Control Payment”) to each Holder to repurchase all or any part (equal to $2,000 and integral multiples of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash equal to not less than 101% of the aggregate principal amount of Notes repurchased plus accrued and unpaid interest if any, to the date of repurchase (the “Change of Control Payment Date,” which date will be no earlier than the date of the corresponding Change of Control). No later than 30 days following any Change of Control, the Company will deliver a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Company will be required to make an Asset Sale Offer, Excess Loss Proceeds Offer, PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer to the extent provided in Sections 4.12, 4.19, 4.20 and 4.21, respectively, of the Indenture.

(8) NOTICE OF REDEMPTION. Notice of redemption will be mailed at least 10 days but not more than 60 days before the redemption date to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes of a series or a satisfaction or discharge of the Indenture. Notes in denominations larger than $2,000 may be redeemed in part but only in whole multiples of $1,000 in excess thereof, unless all of the Notes held by a Holder are to be redeemed.

 

A-3-4


(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form without coupons in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Company may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Company need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Company need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the corresponding Interest Payment Date.

(10) PERSONS DEEMED OWNERS. The registered Holder of a Note may be treated as its owner for all purposes.

(11) TRUSTEE DEALINGS WITH COMPANY. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Company or its Affiliates, and may otherwise deal with the Company or its Affiliates, as if it were not the Trustee.

(12) NO RECOURSE AGAINST OTHERS.

No past, present or future director, manager, officer, employee, incorporator, member, partner, Affiliate or stockholder of the Company or any Guarantor (in each case other than the Company and the Guarantors) or the Sponsor, as such, will have any liability for any obligations of the Company or the Guarantors under the Notes, this Indenture, the Note Guarantees, the Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(13) AUTHENTICATION. This Note will not be valid until authenticated by the manual or electronic signature of the Trustee or an authenticating agent.

(14) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(15) CUSIP NUMBERS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Company has caused CUSIP numbers to be printed on the Notes, and the Trustee may use CUSIP numbers in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

 

A-3-5


(16) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THIS NOTE AND THE NOTE GUARANTEES.

The Company will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Facsimile No.: [***]

Attention: Treasurer

 

A-3-6


ASSIGNMENT FORM

To assign this Note, fill in the form below:

 

(I) or (we) assign and transfer this Note to:     
   (Insert assignee’s legal name)

 

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

 

 

 

 

(Print or type assignee’s name, address and zip code)

and irrevocably                                           appoint to transfer this Note on the books of the Company. The agent may substitute another to act for him.

Date:       

 

Your Signature:    
  (Sign exactly as your name appears on the face of this Note)

Signature Guarantee*:                

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A-3-7


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, check the appropriate box below:

 

☐ Section 4.12

  

☐ Section 4.17

  

☐ Section 4.19

  

☐ Section 4.20

☐ Section 4.21

        

If you want to elect to have only part of the Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, state the amount you elect to have purchased:

$      

Date:      

 

Your Signature:    
  (Sign exactly as your name appears on the face of this Note)

Tax Identification No:

   

Signature Guarantee*:             

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A-3-8


SCHEDULE OF EXCHANGES OF INTERESTS IN THE GLOBAL NOTE

The following exchanges of a part of this Global Note for an interest in another Global Note or for a Definitive Note, or exchanges of a part of another Global Note or Definitive Note for an interest in this Global Note, have been made:

 

Date of

Exchange

 

Amount of

decrease in

Principal

Amount [at

maturity] of

this Global

Note

 

Amount of

increase in

Principal

Amount [at

maturity] of

this Global

Note

  

Principal

Amount [at

maturity] of

this Global

Note following

such decrease

(or increase)

  

Signature of

authorized

signatory of

Trustee or

Custodian

 

A-3-9


EXHIBIT A-4

[Face of Regulation S Temporary Global Note]

CUSIP: U9220M AB9

ISIN: USU9220MAB91

4.125% Senior Secured Notes due 2031

 

No.          $     

VENTURE GLOBAL CALCASIEU PASS, LLC

promises to pay to        or registered assigns, the principal sum of                       DOLLARS on August 15, 2031.

Interest Payment Dates: February 15 and August 15, commencing February 15, 2022

Record Dates: February 1 and August 1

Dated:      , 20

 

VENTURE GLOBAL CALCASIEU PASS, LLC
By:    
Name:  
Title:  

 

This is one of the Notes referred to

in the within-mentioned Indenture:

  

THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A.,
as Trustee

  

 

By:    
  Authorized Signatory
Dated:     , 20

 

A-4-1


[Back of Regulation S Temporary Global Note]

4.125% Senior Secured Notes due 2031

THE RIGHTS ATTACHING TO THIS REGULATION S TEMPORARY GLOBAL NOTE, AND THE CONDITIONS AND PROCEDURES GOVERNING ITS EXCHANGE FOR CERTIFICATED NOTES, ARE AS SPECIFIED IN THE INDENTURE (AS DEFINED HEREIN). NEITHER THE HOLDER NOR THE BENEFICIAL OWNERS OF THIS REGULATION S TEMPORARY GLOBAL NOTE SHALL BE ENTITLED TO RECEIVE PAYMENT OF INTEREST HEREON.

THIS GLOBAL NOTE IS HELD BY THE DEPOSITARY (AS DEFINED IN THE INDENTURE GOVERNING THIS NOTE) OR ITS NOMINEE IN CUSTODY FOR THE BENEFIT OF THE BENEFICIAL OWNERS HEREOF, AND IS NOT TRANSFERABLE TO ANY PERSON UNDER ANY CIRCUMSTANCES EXCEPT THAT (1) THE TRUSTEE MAY MAKE SUCH NOTATIONS HEREON AS MAY BE REQUIRED PURSUANT TO SECTION 2.06 OF THE INDENTURE, (2) THIS GLOBAL NOTE MAY BE EXCHANGED IN WHOLE BUT NOT IN PART PURSUANT TO SECTION 2.06(a) OF THE INDENTURE, (3) THIS GLOBAL NOTE MAY BE DELIVERED TO THE TRUSTEE FOR CANCELLATION PURSUANT TO SECTION 2.11 OF THE INDENTURE AND (4) THIS GLOBAL NOTE MAY BE TRANSFERRED TO A SUCCESSOR DEPOSITARY WITH THE PRIOR WRITTEN CONSENT OF THE COMPANY.

UNLESS AND UNTIL IT IS EXCHANGED IN WHOLE OR IN PART FOR NOTES IN DEFINITIVE FORM, THIS NOTE MAY NOT BE TRANSFERRED EXCEPT AS A WHOLE BY THE DEPOSITARY TO A NOMINEE OF THE DEPOSITARY OR BY A NOMINEE OF THE DEPOSITARY TO THE DEPOSITARY OR ANOTHER NOMINEE OF THE DEPOSITARY OR BY THE DEPOSITARY OR ANY SUCH NOMINEE TO A SUCCESSOR DEPOSITARY OR A NOMINEE OF SUCH SUCCESSOR DEPOSITARY. UNLESS THIS CERTIFICATE IS PRESENTED BY AN AUTHORIZED REPRESENTATIVE OF THE DEPOSITORY TRUST COMPANY (55 WATER STREET, NEW YORK, NEW YORK) (“DTC”), TO THE COMPANY OR ITS AGENT FOR REGISTRATION OF TRANSFER, EXCHANGE OR PAYMENT, AND ANY CERTIFICATE ISSUED IS REGISTERED IN THE NAME OF CEDE & CO. OR SUCH OTHER NAME AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC (AND ANY PAYMENT IS MADE TO CEDE & CO. OR SUCH OTHER ENTITY AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC), ANY TRANSFER, PLEDGE OR OTHER USE HEREOF FOR VALUE OR OTHERWISE BY OR TO ANY PERSON IS WRONGFUL INASMUCH AS THE REGISTERED OWNER HEREOF, CEDE & CO., HAS AN INTEREST HEREIN.

THIS NOTE HAS NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), AND MAY NOT BE OFFERED, SOLD, PLEDGED OR OTHERWISE TRANSFERRED EXCEPT IN ACCORDANCE WITH THE FOLLOWING SENTENCE. BY ITS ACQUISITION HEREOF OR OF A BENEFICIAL INTEREST HEREIN, THE ACQUIRER AGREES FOR THE BENEFIT OF VENTURE GLOBAL CALCASIEU PASS, LLC THAT IT WILL NOT OFFER, SELL, PLEDGE OR OTHERWISE TRANSFER THIS NOTE OR ANY BENEFICIAL INTEREST HEREIN, EXCEPT IN ACCORDANCE WITH THE SECURITIES ACT AND ANY APPLICABLE SECURITIES LAWS OF ANY

 

A-4-2


STATE OF THE UNITED STATES AND ONLY (A) TO VENTURE GLOBAL CALCASIEU PASS, LLC, (B) PURSUANT TO A REGISTRATION STATEMENT WHICH HAS BECOME EFFECTIVE UNDER THE SECURITIES ACT, (C) TO A QUALIFIED INSTITUTIONAL BUYER IN COMPLIANCE WITH RULE 144A UNDER THE SECURITIES ACT, (D) IN AN OFFSHORE TRANSACTION IN COMPLIANCE WITH RULE 904 OF REGULATION S UNDER THE SECURITIES ACT, (E) TO AN INSTITUTIONAL “ ACCREDITED INVESTOR” WITHIN THE MEANING OF RULE 501(a)(1), (2), (3) OR (7) UNDER THE SECURITIES ACT THAT IS NOT A QUALIFIED INSTITUTIONAL BUYER AND THAT IS PURCHASING FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF ANOTHER INSTITUTIONAL ACCREDITED INVESTOR, IN EACH CASE IN A MINIMUM PRINCIPAL AMOUNT OF THE SECURITIES OF $250,000, FOR INVESTMENT PURPOSES AND NOT WITH A VIEW TO OR FOR OFFER OR SALE IN CONNECTION WITH ANY DISTRIBUTION IN VIOLATION OF THE SECURITIES ACT OR (F) PURSUANT TO AN EXEMPTION FROM REGISTRATION PROVIDED BY RULE 144 UNDER THE SECURITIES ACT OR ANY OTHER AVAILABLE EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT. PRIOR TO THE REGISTRATION OF ANY TRANSFER IN ACCORDANCE WITH CLAUSES (C), (D) OR (E) ABOVE, A DULY COMPLETED AND SIGNED CERTIFICATE (THE FORM OF WHICH MAY BE OBTAINED FROM THE TRUSTEE) MUST BE DELIVERED TO THE TRUSTEE. PRIOR TO THE REGISTRATION OF ANY TRANSFER IN ACCORDANCE WITH (F) ABOVE, VENTURE GLOBAL CALCASIEU PASS, LLC RESERVES THE RIGHT TO REQUIRE THE DELIVERY OF SUCH LEGAL OPINIONS, CERTIFICATIONS OR OTHER EVIDENCE AS MAY REASONABLY BE REQUIRED IN ORDER TO DETERMINE THAT THE PROPOSED TRANSFER IS BEING MADE IN COMPLIANCE WITH THE SECURITIES ACT AND APPLICABLE STATE SECURITIES LAWS. NO REPRESENTATION IS MADE AS TO THE AVAILABILITY OF ANY RULE 144 EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT.

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Company”), promises to pay interest on the principal amount of this Note at 4.125% per annum from August 5, 2021 until maturity. The Company will pay interest semi-annually in arrears on February 15 and August 15 of each year, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from the date of issuance; provided that if there is no existing Unmatured Event of Default or Event of Default in the payment of interest, and if this Note is authenticated between a record date referred to on the face hereof and the next succeeding Interest Payment Date, interest shall accrue from such next succeeding Interest Payment Date; provided further that the first Interest Payment Date shall be February 15, 2022. The Company will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue principal and premium, if any, from time to time on demand at a rate that is 0.50% per annum in excess of the rate then in effect to the extent lawful; it will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue installments of interest (without regard to any applicable grace periods) from time to time on demand at the rate equal to 0.50% per annum in excess of the then applicable interest rate on the Notes of such series to the extent lawful. Interest will be computed on the basis of a 360-day year of twelve 30-day months.

 

A-4-3


Until this Regulation S Temporary Global Note is exchanged for one or more Regulation S Permanent Global Notes, the Holder hereof shall not be entitled to receive payments of interest hereon; until so exchanged in full, this Regulation S Temporary Global Note shall in all other respects be entitled to the same benefits as other Notes under the Indenture.

(2) METHOD OF PAYMENT. The Company will pay interest on the Notes (except defaulted interest) to the Persons who are registered Holders of Notes at the close of business on the February 1 or August 1 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium and interest at the office or agency of the Paying Agent or Registrar maintained for such purpose within or without the City and State of New York, or, at the option of the Company, payment of interest may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that payment by wire transfer of immediately available funds will be required with respect to principal of and interest, premium on, all Global Notes and all other Notes the Holders of which will have provided wire transfer instructions to the Company or the Paying Agent. Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Company may change any Paying Agent or Registrar without notice to any Holder. The Company or any of its Subsidiaries may act in any such capacity.

(4) INDENTURE AND SECURITY DOCUMENTS. The Company issued the Notes under an Indenture dated as of August 5, 2021 (the “Indenture”) among the Company, TCP and the Trustee. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are secured obligations of the Company. The Notes are secured by a pledge of Collateral (as defined in the Indenture) pursuant to the Security Documents referred to in the Indenture. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

At any time or from time to time prior to February 15, 2031 (the “2031 Call Date”), the Company may, at its option, redeem all or a part of the 2031 Notes at a redemption price equal to the 2031 Make-Whole Price plus accrued and unpaid interest on such 2031 Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

 

A-4-4


2031 Make-Whole Price” with respect to any 2031 Notes to be redeemed, means an amount equal to the greater of:

(1) 100% of the principal amount of such 2031 Notes, without any premium, penalty or charge; and

(3) an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2031 Call Date (assuming the principal amount is scheduled to be paid on the 2031 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate (as defined below) plus 50 basis points.

At any time on or after the 2031 Call Date, the Company may, at its option, redeem all or a part of the 2031 Notes, at a redemption price equal to 100% of the principal amount of the 2031 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

Treasury Rate” means the yield to maturity at the time of computation of United States Treasury securities with a constant maturity (as compiled and published in the most recent Federal Reserve Statistical Release H.15 (519) which has become publicly available at least two Business Days (but not more than five Business Days) prior to the relevant redemption date (or, if such Statistical Release is not so published or available, any publicly available source of similar market data selected by the Company in good faith)) most nearly equal to the period from the redemption date to the 2031 Call Date on which the principal of the 2031 Notes being redeemed will be paid in full; provided, however, that if the period from the redemption date to such 2031 Call Date is not equal to the constant maturity of a United States Treasury security for which a weekly average yield is given, the Treasury Rate shall be obtained by linear interpolation (calculated to the nearest one-twelfth of a year) from the weekly average yields of United States Treasury securities for which such yields are given, except that if the period from the redemption date to such 2031 Call Date is less than one year, the weekly average yield on actually traded United States Treasury securities adjusted to a constant maturity of one year shall be used.

The notice of redemption with respect to the foregoing redemption need not set forth the 2031 Make-Whole Price, but only the manner of calculation thereof. The Company will determine the redemption price (including any 2031 Make-Whole Price) and will notify the Trustee of the redemption price (including any 2031 Make-Whole Price) with respect to any redemption promptly, and the Trustee shall not be responsible for such calculation or determination.

(6) MANDATORY REDEMPTION.

The Company is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

 

A-4-5


(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control, the Company will make an offer (a “Change of Control Offer”) of payment (a “Change of Control Payment”) to each Holder to repurchase all or any part (equal to $2,000 and integral multiples of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash equal to not less than 101% of the aggregate principal amount of Notes repurchased plus accrued and unpaid interest if any, to the date of repurchase (the “Change of Control Payment Date,” which date will be no earlier than the date of the corresponding Change of Control). No later than 30 days following any Change of Control, the Company will deliver a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Company will be required to make an Asset Sale Offer, Excess Loss Proceeds Offer, PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer to the extent provided in Sections 4.12, 4.19, 4.20 and 4.21, respectively, of the Indenture.

(8) NOTICE OF REDEMPTION. Notice of redemption will be mailed at least 10 days but not more than 60 days before the redemption date to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes of a series or a satisfaction or discharge of the Indenture. Notes in denominations larger than $2,000 may be redeemed in part but only in whole multiples of $1,000 in excess thereof, unless all of the Notes held by a Holder are to be redeemed.

(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form without coupons in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Company may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Company need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Company need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the corresponding Interest Payment Date.

(10) PERSONS DEEMED OWNERS. The registered Holder of a Note may be treated as its owner for all purposes.

(11) TRUSTEE DEALINGS WITH COMPANY. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Company or its Affiliates, and may otherwise deal with the Company or its Affiliates, as if it were not the Trustee.

 

A-4-6


(12) NO RECOURSE AGAINST OTHERS.

No past, present or future director, manager, officer, employee, incorporator, member, partner, Affiliate or stockholder of the Company or any Guarantor (in each case other than the Company and the Guarantors) or the Sponsor, as such, will have any liability for any obligations of the Company or the Guarantors under the Notes, this Indenture, the Note Guarantees, the Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(13) AUTHENTICATION. This Note will not be valid until authenticated by the manual or electronic signature of the Trustee or an authenticating agent.

(14) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(15) CUSIP NUMBERS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Company has caused CUSIP numbers to be printed on the Notes, and the Trustee may use CUSIP numbers in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

(16) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THIS NOTE AND THE NOTE GUARANTEES.

The Company will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Facsimile No.: [***]

Attention: Treasurer

 

A-4-7


ASSIGNMENT FORM

To assign this Note, fill in the form below:

 

(I) or (we) assign and transfer this Note to:     
   (Insert assignee’s legal name)

 

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

 

 

 

 

(Print or type assignee’s name, address and zip code)

and irrevocably                                           appoint to transfer this Note on the books of the Company. The agent may substitute another to act for him.

Date:       

 

Your Signature:    
  (Sign exactly as your name appears on the face of this Note)

Signature Guarantee*:                

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A-4-8


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, check the appropriate box below:

 

☐ Section 4.12

  

☐ Section 4.17

  

☐ Section 4.19

  

☐ Section 4.20

☐ Section 4.21

        

If you want to elect to have only part of the Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, state the amount you elect to have purchased:

$      

Date:      

 

Your Signature:    
  (Sign exactly as your name appears on the face of this Note)

Tax Identification No:

   

Signature Guarantee*:             

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A-4-9


SCHEDULE OF EXCHANGES OF INTERESTS IN THE REGULATION S

TEMPORARY GLOBAL NOTE

The following exchanges of a part of this Regulation S Temporary Global Note for an interest in another Global Note, or exchanges of a part of another other Restricted Global Note or for an interest in this Regulation S Temporary Global Note, have been made:

 

Date of

Exchange

 

Amount of

decrease in

Principal

Amount [at

maturity] of

this Global

Note

 

Amount of

increase in

Principal

Amount [at

maturity] of

this Global

Note

  

Principal

Amount [at

maturity] of

this Global

Note following

such decrease

(or increase)

  

Signature of

authorized

signatory of

Trustee or

Custodian

 

A-4-10


EXHIBIT B

FORM OF CERTIFICATE OF TRANSFER

The Bank of New York Mellon Trust Company, N.A., as Trustee

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

 

cc:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

 

Re:

  % Senior Secured Notes due 20 issued by Venture Global Calcasieu Pass, LLC

Reference is hereby made to the Indenture, dated as of August 5, 2021, (the “Indenture”), among Venture Global Calcasieu Pass, LLC, as issuer (the “Company”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as trustee. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

            , (the “Transferor”) owns and proposes to transfer the Note[s] or interest in such Note[s] specified in Annex A hereto, in the principal amount of $      in such Note[s] or interests (the “Transfer”), to         (the “Transferee”), as further specified in Annex A hereto. In connection with the Transfer, the Transferor hereby certifies that:

[CHECK ALL THAT APPLY]

 

  1.

Check if Transferee will take delivery of a beneficial interest in the Rule 144A Global Note or a Restricted Definitive Note pursuant to Rule 144A. The Transfer is being effected pursuant to and in accordance with Rule 144A (“Rule 144A”) under the Securities Act of 1933, as amended (the “Securities Act”), and, accordingly, the Transferor hereby further certifies that the beneficial interest or Definitive Note is being transferred to a Person that the Transferor reasonably believes is purchasing the beneficial interest or Definitive Note for its own account, or for one or more accounts with respect to which such Person exercises sole investment discretion, and such Person and each such account is a “qualified institutional buyer” within the meaning of Rule 144A in a transaction meeting the requirements of Rule 144A, and such Transfer is in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Rule 144A Global Note and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

 

B-1


  2.

Check if Transferee will take delivery of a beneficial interest in the Regulation S Temporary Global Note, the Regulation S Permanent Global Note or a Restricted Definitive Note pursuant to Regulation S. The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and, accordingly, the Transferor hereby further certifies that (i) the Transfer is not being made to a Person in the United States and (x) at the time the buy order was originated, the Transferee was outside the United States or such Transferor and any Person acting on its behalf reasonably believed and believes that the Transferee was outside the United States or (y) the transaction was executed in, on or through the facilities of a designated offshore securities market and neither such Transferor nor any Person acting on its behalf knows that the transaction was prearranged with a buyer in the United States, (ii) no directed selling efforts have been made in contravention of the requirements of Rule 903(b) or Rule 904(b) of Regulation S under the Securities Act, (iii) the transaction is not part of a plan or scheme to evade the registration requirements of the Securities Act and (iv) if the proposed transfer is being made prior to the expiration of the Restricted Period, (x) the transfer is not being made to a U.S. Person or for the account or benefit of a U.S. Person (other than the Initial Purchasers of the Notes) and (y) the interest transferred will be held immediately thereafter through Euroclear or Clearstream. Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on Transfer enumerated in the Private Placement Legend printed on the Regulation S Permanent Global Note, the Regulation S Temporary Global Note and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

 

  3.

Check and complete if Transferee will take delivery of a beneficial interest in a Restricted Definitive Note pursuant to any provision of the Securities Act other than Rule 144A or Regulation S. The Transfer is being effected in compliance with the transfer restrictions applicable to beneficial interests in Restricted Global Notes and Restricted Definitive Notes and pursuant to and in accordance with the Securities Act and any applicable blue sky securities laws of any state of the United States, and accordingly the Transferor hereby further certifies that (check one):

(a) ☐ such Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act;

or

(b) ☐ such Transfer is being effected to the Company or a subsidiary thereof;

or

(c) ☐ such Transfer is being effected pursuant to an effective registration statement under the Securities Act and in compliance with the prospectus delivery requirements of the Securities Act;

 

B-2


or

(d) ☐ such Transfer is being effected to an Institutional Accredited Investor and pursuant to an exemption from the registration requirements of the Securities Act other than Rule 144A, Rule 144, Rule 903 or Rule 904, and the Transferor hereby further certifies that it has not engaged in any general solicitation within the meaning of Regulation D under the Securities Act and the Transfer complies with the transfer restrictions applicable to beneficial interests in a Restricted Global Note or Restricted Definitive Notes and the requirements of the exemption claimed, which certification is supported by (1) a certificate executed by the Transferee in the form of Exhibit G to the Indenture and (2) if such Transfer is in respect of a principal amount of Notes at the time of transfer of less than $250,000, an Opinion of Counsel provided by the Transferor or the Transferee (a copy of which the Transferor has attached to this certification), to the effect that such Transfer is in compliance with the Securities Act. Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the IAI Global Note and/or the Restricted Definitive Notes and in the Indenture and the Securities Act.

 

  4.

Check if Transferee will take delivery of a beneficial interest in an Unrestricted Global Note or of an Unrestricted Definitive Note.

(a) ☐ Check if Transfer is pursuant to Rule 144. (i) The Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

(b) ☐ Check if Transfer is Pursuant to Regulation S. (i) The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

 

B-3


(c) ☐ Check if Transfer is Pursuant to Other Exemption. (i) The Transfer is being effected pursuant to and in compliance with an exemption from the registration requirements of the Securities Act other than Rule 144, Rule 903 or Rule 904 and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any State of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will not be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes or Restricted Definitive Notes and in the Indenture.

This certificate and the statements contained herein are made for your benefit and the benefit of the Company.

 

 
[Insert Name of Transferor]
By:    
Name:  
Title:  

Dated:       

 

B-4


ANNEX A TO CERTIFICATE OF TRANSFER

 

  1.

The Transferor owns and proposes to transfer the following:

[CHECK ONE OF (a) OR (b)]

 

  (a)

☐ a beneficial interest in the:

 

  (i)

☐ Rule 144A Global Note (CUSIP     ), or

 

  (ii)

☐ Regulation S Global Note (CUSIP     ); or

 

  (iii)

☐ IAI Global Note (CUSIP     ); or

 

  (b)

☐ a Restricted Definitive Note.

 

  2.

After the Transfer the Transferee will hold:

[CHECK ONE]

 

  (a)

☐ a beneficial interest in the:

 

  (i)

☐ Rule 144A Global Note (CUSIP     ), or

 

  (ii)

☐ Regulation S Global Note (CUSIP     ); or

 

  (iii)

☐ IAI Global Note (CUSIP     ); or

 

  (iv)

☐ Unrestricted Global Note (CUSIP     ).

 

  (b)

☐ Restricted Definitive Note; or

 

  (c)

☐ an Unrestricted Definitive Note,

in accordance with the terms of the Indenture.

 

B-5


EXHIBIT C

FORM OF CERTIFICATE OF EXCHANGE

The Bank of New York Mellon Trust Company, N.A., as Trustee

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

 

cc:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

 

Re:

  % Senior Secured Notes due 20 issued by Venture Global Calcasieu Pass, LLC

(CUSIP     )

Reference is hereby made to the Indenture, dated as of August 5, 2021, (the “Indenture”), among Venture Global Calcasieu Pass, LLC, as issuer (the “Company”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as trustee. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

         , (the “Owner”) owns and proposes to exchange the Note[s] or interest in such Note[s] specified herein, in the principal amount of $     in such Note[s] or interests (the “Exchange”). In connection with the Exchange, the Owner hereby certifies that:

1. Exchange of Restricted Definitive Notes or Beneficial Interests in a Restricted Global Note for Unrestricted Definitive Notes or Beneficial Interests in an Unrestricted Global Note

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to beneficial interest in an Unrestricted Global Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a beneficial interest in an Unrestricted Global Note in an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Global Notes and pursuant to and in accordance with the Securities Act of 1933, as amended (the “Securities Act”), (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest in an Unrestricted Global Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

 

C-1


(b) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Unrestricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(c) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in an Unrestricted Global Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for a beneficial interest in an Unrestricted Global Note, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(d) ☐ Check if Exchange is from Restricted Definitive Note to Unrestricted Definitive Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Unrestricted Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Unrestricted Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

2. Exchange of Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes for Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Restricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a Restricted Definitive Note with an equal principal amount, the Owner hereby certifies that the Restricted Definitive Note is being acquired for the Owner’s own account without transfer. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the Restricted Definitive Note issued will continue to be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Definitive Note and in the Indenture and the Securities Act.

(b) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in a Restricted Global Note. In connection with the Exchange of the Owner’s Restricted Definitive Note for a beneficial interest in the [CHECK ONE] ☐ 144A Global Note or ☐ Regulation S Global Note or ☐ IAI Global Note with an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer and (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, and in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the beneficial interest issued will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the relevant Restricted Global Note and in the Indenture and the Securities Act.

 

C-2


This certificate and the statements contained herein are made for your benefit and the benefit of the Company.

 

     

[Insert Name of Transferor]

By:    

Name:

Title:

Dated: ____________

 

C-3


EXHIBIT D

[FORM OF NOTATION OF GUARANTEE]

For value received, each Guarantor (which term includes any successor Person under the Indenture) has, jointly and severally, unconditionally guaranteed, to the extent set forth and subject to the provisions in the Indenture dated as of August 5, 2021 (the “Indenture”) among Venture Global Calcasieu Pass, LLC (the “Company”) the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as trustee (the “Trustee”) and the provisions of Section 11 of the Common Security and Account Agreement (the “Common Security and Account Agreement”), dated as of August 19, 2019, among the Company, TCP, the other Guarantors party thereto, each Senior Creditor Group Representative, the Intercreditor Agent, the Collateral Agent and the Account Bank (as such terms are defined therein), (a) the due and punctual payment of the principal of, premium and interest on, the Notes, whether at maturity, by acceleration, redemption or otherwise, the due and punctual payment of interest on overdue principal of and interest on the Notes, if any, if lawful, and the due and punctual performance of all other obligations of the Company to the Holders or the Trustee all in accordance with the terms of the Indenture and (b) in case of any extension of time of payment or renewal of any Notes or any of such other obligations, that the same will be promptly paid in full when due or performed in accordance with the terms of the extension or renewal, whether at stated maturity, by acceleration or otherwise. The obligations of the Guarantors to the Holders of Notes and to the Trustee pursuant to the Note Guarantee and the Indenture are expressly set forth in Article 11 of the Indenture and Section 11 of the Common Security and Account Agreement and reference is hereby made to the Indenture for the precise terms of the Note Guarantee. Each Holder of a Note, by accepting the same, agrees to and shall be bound by such provisions.

Capitalized terms used but not defined herein have the meanings given to them in the Indenture.

 

[NAME OF GUARANTOR(S)]
By:    
Name:  
Title:  

 

D-1


EXHIBIT E

[FORM OF SUPPLEMENTAL INDENTURE

TO BE DELIVERED BY SUBSEQUENT GUARANTORS]

SUPPLEMENTAL INDENTURE (this “Supplemental Indenture”), dated as of     , 20    , among     (the “Guaranteeing Subsidiary”), a subsidiary of Venture Global Calcasieu Pass, LLC (or its permitted successor), a Delaware limited liability company (the “Company”), the Company, the other Guarantors (as defined in the Indenture referred to herein) and The Bank of New York Mellon Trust Company, N.A., as trustee under the Indenture referred to below (the “Trustee”).

W I T N E S S E T H

WHEREAS, the Company has heretofore executed and delivered to the Trustee an indenture (the “Indenture”), dated as of August 5, 2021 providing for the issuance of 3.875% Senior Secured Notes due 2029 (the “2029 Notes”) and 4.125% Senior Secured Notes due 2031 (the “2031 Notes” and, together with the 2029 Notes, the “Notes”);

WHEREAS, the Indenture provides that under certain circumstances the Guaranteeing Subsidiary shall execute and deliver to the Trustee a supplemental indenture pursuant to which the Guaranteeing Subsidiary shall unconditionally guarantee all of the Company’s obligations under the Notes and the Indenture on the terms and conditions set forth herein (the “Note Guarantee”); and

WHEREAS, pursuant to Section 9.01 of the Indenture, the Trustee is authorized to execute and deliver this Supplemental Indenture.

NOW, THEREFORE, in consideration of the foregoing and for other good and valuable consideration, the receipt of which is hereby acknowledged, the Guaranteeing Subsidiary and the Trustee mutually covenant and agree for the equal and ratable benefit of the Holders as follows:

1. CAPITALIZED TERMS. Capitalized terms used herein without definition shall have the meanings assigned to them in the Indenture.

2. AGREEMENT TO GUARANTEE. The Guaranteeing Subsidiary hereby agrees to provide an unconditional Guarantee on the terms and subject to the conditions set forth in the Note Guarantee and in the Indenture including but not limited to Article 11 thereof and Section 11 of the Common Security and Account Agreement dated as of August 19, 2019, among the Company, TCP, the other Guarantors party thereto, each Senior Creditor Group Representative, the Intercreditor Agent, the Collateral Agent and the Account Bank (as such terms are defined therein).

3. NO RECOURSE AGAINST OTHERS. No past, present or future director, officer, employee, incorporator, stockholder or agent of the Guaranteeing Subsidiary, as such, shall have any liability for any obligations of the Company or any Guaranteeing Subsidiary under the Notes, any Note Guarantees, the Indenture or this Supplemental Indenture or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder of the Notes by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes.

 

E-1


4. NEW YORK LAW TO GOVERN. THE LAW OF THE STATE OF NEW YORK SHALL GOVERN AND BE USED TO CONSTRUE THIS SUPPLEMENTAL INDENTURE WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

5. EXECUTION; COUNTERPARTS. The parties may manually or electronically sign any number of copies of this Supplemental Indenture. Each signed copy shall be an original, but all of them together represent the same agreement. Delivery of an executed Supplemental Indenture by one party to any other party may be made by facsimile, electronic mail (including any electronic signature complying with the New York Electronic Signatures and Records Act (N.Y. State Tech. §§ 301-309), as amended from time to time, or other applicable law), including DocuSign, or other transmission method, and the parties hereto agree that any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

6. Effect of Headings. The Section headings herein are for convenience only and shall not affect the construction hereof.

7. THE TRUSTEE. The Trustee shall not be responsible in any manner whatsoever for or in respect of the validity or sufficiency of this Supplemental Indenture or for or in respect of the recitals contained herein, all of which recitals are made solely by the Guaranteeing Subsidiary and the Company.

 

E-2


IN WITNESS WHEREOF, the parties hereto have caused this Supplemental Indenture to be duly executed and attested, all as of the date first above written.

Dated:     , 20

 

[GUARANTEEING SUBSIDIARY]

By:    
Name:  
Title:  

VENTURE GLOBAL CALCASIEU PASS, LLC

By:    
Name:  
Title:  

[EXISTING GUARANTORS]

By:    
Name:  
Title:  
THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A.
 as Trustee
By:    
 

Authorized Signatory

 

E-3


EXHIBIT F

Additional Notes and Supplemental Indentures for Additional Notes

Reference is made in this Exhibit F to the Indenture dated as of August 5, 2021 (the “Indenture”) among Venture Global Calcasieu Pass, LLC, (the “Company”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as trustee (the “Trustee”).

(a) After the Notes Issue Date, subject to compliance with the Indenture, including Sections 2.01 and 4.08 thereof and this Exhibit F, the Company may issue Additional Notes, in one or more series, under this Indenture or under one or more Supplemental Indentures that comply with the provisions of this Indenture. Additional Notes may be issued as a separate series or the same series as the Initial Notes or other Additional Notes, as shall be specified in the form of the Additional Note or in any Supplemental Indenture governing the terms of the Additional Notes permitted to be issued by this Indenture. Additional Notes may be issued in accordance with the following provisions, which are deemed to be part of Section 2.01(d) of the Indenture:

(b) Capitalized terms used and not otherwise defined in this Exhibit F which are defined in Section 2.01(b) or other Sections of the Indenture have the meanings set forth therein and the following terms have the meanings set forth below:

Board Resolution” means a resolution duly adopted by (1) the Board of Directors (or equivalent governing body) of the Company or (2) any pricing or other committee of the Board of Directors (or equivalent governing body) of the Company duly authorized to act for it hereunder, a copy of which is delivered to the Trustee, accompanied by an Officer’s Certificate that such resolution has been duly adopted, has not been amended, modified, supplemented or rescinded and is in full force and effect.

Registered Additional Note” means any Additional Note registered on the Additional Note Register maintained by the Company pursuant to Section 3.01 below.

1.01. Terms of Additional Notes. (a) The terms and conditions of any Additional Notes shall be established in or pursuant to a Board Resolution, and set forth in an Officer’s Certificate, or established in one or more Supplemental Indentures approved pursuant to a Board Resolution, and as set forth in an Officer’s Certificate, prior to the issuance of Additional Notes of any series, which shall include, as applicable:

(i) the title of the Additional Notes of the series (which shall distinguish the Additional Notes of the series from all other Notes);

(ii) any limit upon the aggregate principal amount of the Additional Notes of the series which may be authenticated and delivered under the Indenture (except for Additional Notes authenticated and delivered upon registration of transfer of, or in exchange for, or in lieu of, other Additional Notes of the series) which amount must be in compliance with the Indenture;

 

F-1


(iii) the date or dates (or the manner of determining the same) on which the principal of the Additional Notes of the series is payable (which, if so provided in or pursuant to such Board Resolution or in any Supplemental Indenture, may be determined by the Company from time to time and set forth in the Additional Notes of the series issued from time to time);

(iv) the rate or rates (or the method of determining the same) at which the Additional Notes of the series shall bear interest, if any, and the date or dates from which such interest shall accrue (which, in the case of either or both, if so provided in or pursuant to such Board Resolution or in any Supplemental Indenture, may be determined by the Company from time to time and set forth in the Additional Notes of the series issued from time to time), the interest payment dates (or the manner of determining the same) on which such interest, if any, shall be payable, the record dates (or the manner of determining the same), if any, for the determination of Holders to whom interest is payable on any interest payment date;

(v) the place or places where, subject to the Indenture, the principal of (and premium, if any) and interest, if any, on Additional Notes of the series shall be payable, any Additional Notes of the series may be surrendered for registration of transfer and Additional Notes of the series may be surrendered for exchange and the place or places where notices or demands to or upon the Company in respect of the Additional Notes of the series may be served;

(vi) the period or periods within which, the price or prices at which, and the terms and conditions upon which Additional Notes of the series may be redeemed, in whole or in part, at the option of the Company, pursuant to any sinking fund or otherwise;

(vii) the obligation, if any, of the Company to redeem, repay, prepay or purchase Additional Notes of the series pursuant to any mandatory prepayment, purchase or redemption provision, sinking fund or analogous provisions or at the option of a Holder thereof and the period or periods within which, the price or prices at which, and the terms and conditions upon which Additional Notes of the series shall be redeemed, repaid, prepaid or purchased, in whole or in part, pursuant to such obligation, or at the option of a Holder thereof;

(viii) if other than denominations of U.S. $1,000 and any integral multiple thereof, the denominations in which Additional Notes of the series shall be issuable;

(ix) if other than the principal amount thereof, the portion of the principal amount of Additional Notes of the series which shall be payable upon declaration of acceleration of the maturity thereof or the method by which such portion shall be determined;

(x) if the amount of payments of principal of (or any premium) or any interest on the Additional Notes of the series may be determined with reference to an index, the manner in which such amounts shall be determined;

 

F-2


(xi) whether the Additional Notes of the series shall be issued in whole or in part in the form of a Global Additional Note or Notes and, in such case, the Depositary for such Global Additional Note or Notes, if other than DTC, whether such global form shall be permanent or temporary and, if so, whether beneficial owners of interests in any such Global Additional Note may exchange such interests for Additional Notes of such series in certificated form and of like tenor of any authorized form and denomination and the circumstances under which any such exchanges may occur, if other than in the manner provided in this Indenture;

(xii) in the case of any Global Additional Note that may be exchanged for other Additional Notes, the manner and procedures for effecting such exchange;

(xiii) whether and under what circumstances, and the terms and conditions on which, the Company will pay additional amounts on the Additional Notes of the series in respect of any tax, assessment or governmental charge withheld or deducted and whether the Company will have the option to redeem such Additional Notes rather than pay such additional amounts or to redeem such Additional Notes in the event of the imposition of any certification, documentation, information or other reporting requirement and, if so, under what circumstances and the terms and conditions on which the Company may exercise such option; and

(xiv) any other terms of the series of Additional Notes which terms must be consistent with the provisions of the Indenture and, with respect to the matters set forth in Articles 4, 5, 6, 9, 10 (if any Additional Note is secured by any Collateral) and 11 (if any Additional Note is guaranteed by any guarantor of the Notes) (and any defined terms used therein) must be the same as those provisions (and any defined terms used therein); provided that (i) any Additional Notes may have multiple principal payments which may be set forth in a schedule to such Additional Notes and (ii) any series of Additional Notes may omit any of the covenants in Article 4 or Events of Default in Article 6.

(b) All Additional Notes of any one series shall be substantially identical except that such Additional Notes may differ as to date of issue and the date from which interest, if any, shall accrue. The terms of such Additional Notes, as set forth above, may be determined by the Company from time to time if so provided in or pursuant to such Board Resolution or in any Supplemental Indenture for Additional Notes. All Additional Notes of any one series need not, but may, be issued at the same time.

(c) If any terms of any series of Additional Notes are established by action taken pursuant to a Board Resolution, a copy of an appropriate record of such action shall be certified by the Secretary or an Assistant Secretary of the Company and delivered to the Trustee at or prior to the delivery of the Officer’s Certificate setting forth the terms of the series.

1.02. Issuance of Additional Notes. (a) When authorized by a Board Resolution, Additional Notes may be issued either pursuant to the Indenture or pursuant to a Supplemental Indenture, in each case, without the consent of the Holders of any Notes, subject to compliance with the provisions of this Indenture.

 

F-3


(b) In authenticating or delivering any Additional Notes under the Indenture, or in executing, or accepting the additional trusts created by, any Supplemental Indenture for Additional Notes permitted by the Indenture, the Trustee shall be entitled to receive, and shall be fully protected in relying upon, and the Company shall cause to be provided, an Opinion of Counsel that (subject to customary exceptions and assumptions):

(i) the form or forms of such Additional Notes and any Supplemental Indenture for Additional Notes have been established in conformity with, and comply with, the provisions of the Indenture;

(ii) the terms of such Additional Notes and any Supplemental Indenture for Additional Notes have been established in conformity with, and comply with, the provisions of the Indenture;

(iii) such Additional Notes, when authenticated and delivered by the Trustee and issued by the Company in the manner and subject to any conditions specified in such Opinion of Counsel, will constitute valid and legally binding obligations of the Company, enforceable in accordance with their terms, subject to bankruptcy, insolvency, reorganization and other laws of general applicability relating to or affecting the enforcement of creditors’ rights and to general equity principles; and

(iv) the execution and delivery by the Company of such Additional Notes and any Supplemental Indenture for Additional Notes (A) have been duly authorized by all necessary limited liability company, managing member or other action on the part of the Company or its members and (B) will not violate the limited liability company agreement, certificate of formation or other organizational documents of the Company, any law binding on the Company, or the Indenture and the other Finance Documents.

In executing any amendment, modification or supplement of any Additional Notes or any Supplemental Indenture for Additional Notes, the Trustee shall be entitled to receive, and shall be fully protected in relying upon, and the Company shall cause to be provided, an Opinion of Counsel stating that the amendment, modification or supplement of any Additional Notes or Supplemental Indenture for Additional Notes is authorized or permitted by the Indenture.

(c) The Trustee and the Company, at any time and from time to time, may enter into one or more Supplemental Indentures, in form satisfactory to the Trustee, (i) to establish the forms or terms of Additional Notes of any series permitted by this Indenture or (ii) to amend such forms or terms in any manner, solely to the extent such amendment is permitted by the terms of this Indenture. The Trustee may, but shall not be obligated to, enter into any such Supplemental Indenture for Additional Notes which affects the Trustee’s own rights, duties or immunities under this Indenture or otherwise.

(d) Upon the execution of any Supplemental Indenture for Additional Notes, any such Supplemental Indenture shall form a part of this Indenture for purposes of such Additional Notes and upon the execution of any amendment, modification or supplement of any Supplemental Indenture for Additional Notes in accordance with this Indenture, the Holders of Additional Notes of any series affected thereby theretofore or thereafter authenticated and delivered hereunder shall be bound thereby.

 

F-4


(f) Additional Notes of any series authenticated and delivered after the execution of any Supplemental Indenture for Additional Notes may, and shall if required by the Trustee, bear a notation in form approved by the Trustee as to any matter provided for in such Supplemental Indentures. If the Company shall so determine, new Additional Notes of any series, so modified as to conform, in the opinion of the Trustee and the Board of Directors, to any such Supplemental Indenture for Additional Notes may be prepared and executed by the Company and authenticated and delivered by the Trustee in exchange for outstanding Additional Notes of such series.

2.01 Form of Additional Notes. (a) Any Additional Notes of the same series as the Initial Notes will be in the form or forms provided in Sections 2.01(a), (b) or (c), as applicable, of the Indenture.

(b) Any Additional Notes of a separate series from the Initial Notes will be in such form or forms, subject to the compliance with all other provisions of this Indenture, as shall be established in or pursuant to a Board Resolution (and set forth in a Board Resolution or, to the extent established pursuant to (rather than as set forth in) such Board Resolution, in an Officer’s Certificate as to such establishment) or in one or more Supplemental Indentures for the Additional Notes permitted to be issued by this Indenture approved pursuant to a Board Resolution

(c) Except as provided in Section 2.01(b) above, the Additional Notes of each series shall be issued as (i) Registered Additional Notes or (ii) Global Additional Notes.

(d) Additional Notes may be issued, in each case, with such appropriate insertions, omissions, substitutions and other variations as are required or permitted by this Indenture or any Supplemental Indenture for Additional Notes, shall have such legends as may be required by Applicable Law, and may have such letters, numbers or other marks of identification and such other legends or endorsements placed thereon as may be required to comply with the rules of any securities exchange, Depositary or clearing organization, or to conform to usage, as may, consistently herewith, be determined by the officers of the Company executing such Additional Notes, as evidenced by their execution of such Additional Notes.

(e) Each Additional Note (including a Global Additional Note) shall be dated the date of its authentication.

(d) The Company in issuing the Additional Notes may use “CUSIP,” “CINS,” “ISIN” and other reference numbers (if then generally in use), and, if so, the Trustee shall use “CUSIP,” “CINS,” “ISIN” and other such reference numbers in notices as a convenience to Holders; provided that any such notice may state that no representation is made as to the correctness of such numbers either as printed on the Additional Notes or as contained in any notice of a redemption and that reliance may be placed only on the other identification numbers printed on the Additional Notes, and any such redemption shall not be affected by any defect in or omission of such numbers. The Company will promptly notify the Trustee of any changes in the “CUSIP,” “CINS,” “ISIN” or the other such reference numbers.

 

F-5


2.02 Form of Trustee Authentication for Additional Notes.

(a) The Trustee’s Certificate of Authentication on all Additional Notes shall be in substantially the following form:

“This is one of the Additional Notes of the series designated therein referred to in the within-mentioned Indenture.”

 

 

[INSERT NAME OF TRUSTEE],

as Trustee

By    
  Authorized Officer

3.01 Registration, Registration of Transfer and Exchange. (a) If the Additional Notes of or within a series are issuable as a Global Additional Note, the provisions of Section 2.06 of the Indenture shall apply to the transfer and exchange of the Global Additional Note.

(b) If the Additional Notes of or within a series are issuable as a Registered Additional Note that is not a Global Additional Note, the Company shall cause to be kept a register or registers in respect of each series of Additional Notes (herein sometimes referred to as the “Additional Note Register”) in which, subject to such reasonable regulations as it may prescribe, the Company shall provide for the registration of Registered Additional Notes of such series and the registration of transfers of Registered Additional Notes of such series.

(b) Upon surrender for registration of transfer of any Registered Additional Note of any series at the office or agency of the Company maintained for such purpose in respect of such series, but subject to any restrictions thereon, the Company shall execute, and the Trustee shall authenticate and deliver, in the name of the designated transferee or transferees, one or more new Registered Additional Notes of such series of any authorized denominations, of a like stated maturity and aggregate principal amount and with like terms and conditions.

(c) At the option of the Holder, Registered Additional Notes of any series may be exchanged for one or more other Registered Additional Notes of such series of any authorized denominations, of a like stated maturity and aggregate principal amount and with like terms and conditions, upon surrender of the Registered Additional Notes to be exchanged at any such office or agency.

(d) Whenever any Registered Additional Notes are so surrendered for exchange, the Company shall execute, and the Trustee shall authenticate and deliver, the Additional Notes which the Holder making the exchange is entitled to receive.

(f) All Additional Notes issued upon any registration of transfer or exchange of Additional Notes shall be the valid obligations of the Company, evidencing the same debt, and entitled to the same benefits under this Indenture, as the Additional Notes surrendered upon such registration of transfer or exchange.

(g) Every Registered Additional Note of a series presented or surrendered for registration of transfer or exchange shall (if so required by the Company or the Trustee) be duly endorsed, or be accompanied by a written instrument of transfer in form satisfactory to the Company, the Trustee and the Additional Note Registrar in respect of such series duly executed, by the Holder thereof or such Holder’s attorney duly authorized in writing.

 

F-6


(h) No service charge shall be made for any registration of transfer or exchange of Additional Notes, but the Company may require payment of a sum sufficient to cover any tax or other governmental charge that may be imposed in connection with any registration of transfer or exchange of Additional Notes.

(i) The Company shall not be required (A) to issue, register the transfer of or exchange any Additional Note of any series during a period beginning at the opening of business 15 days before the day of the mailing of a notice of redemption of Additional Notes of such series selected for redemption hereunder and ending at the close of business on the day of such mailing or (B) to register the transfer of or exchange any Registered Additional Note of such series so selected for redemption in whole or in part, except the unredeemed portion of any Registered Additional Note being redeemed in part.

3.02 Persons Deemed Owners. (a) The Company, the Trustee and any paying agent, the Additional Note registrar and any other agent of the Company or the Trustee in respect of the Additional Notes of any series may treat the Person in whose name any Registered Additional Note of such series is registered as the owner of such Registered Additional Note for the purpose of receiving payment of principal of (and premium, if any) and interest, if any, on such Registered Additional Note and for all other purposes whatsoever, whether or not such Registered Additional Note be overdue, and neither the Company nor the Trustee nor any paying agent, Additional Note registrar or other agent of the Company or the Trustee in respect of the Registered Additional Notes of such series shall be affected by notice to the contrary.

(b) None of the Company, the Trustee and any paying agent, the Additional Note registrar and any other agent of the Company or the Trustee will have any responsibility or liability for any aspect of the records relating to or payments made on account of beneficial ownership interests of a Global Additional Note or for maintaining, supervising or reviewing any records relating to such beneficial ownership interests.

(c) Notwithstanding the foregoing, with respect to any Global Additional Note, nothing herein shall prevent the Company, the Trustee, or any agent of the Company or the Trustee, from giving effect to any written certification, proxy or other authorization furnished by any Depositary, as a Holder, with respect to such Global Additional Note or impair, as between such Depositary and owners of beneficial interests in such Global Additional Note, the operation of customary practices governing the exercise of the rights of such Depositary (or its nominee) as Holder of such Global Additional Note.

 

F-7


EXHIBIT G

FORM OF CERTIFICATE FROM

ACQUIRING INSTITUTIONAL ACCREDITED INVESTOR

The Bank of New York Mellon Trust Company, N.A., as Trustee

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

 

cc:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

 

Re:

  % Senior Secured Notes due 20 issued by Venture Global Calcasieu Pass, LLC

Reference is hereby made to the Indenture, dated as of August 5, 2021 (the “Indenture”), among Venture Global Calcasieu Pass, LLC, as issuer (the “Company”), the guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as trustee. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

In connection with our proposed purchase of $     aggregate principal amount of:

 

  (a)

☐ a beneficial interest in a Global Note, or

 

  (b)

☐ a Definitive Note,

we confirm that:

1. We understand that any subsequent transfer of the Notes or any interest therein is subject to certain restrictions and conditions set forth in the Indenture and the undersigned agrees to be bound by, and not to resell, pledge or otherwise transfer the Notes or any interest therein except in compliance with, such restrictions and conditions and the Securities Act of 1933, as amended (the “Securities Act”).

2. We understand that the offer and sale of the Notes have not been registered under the Securities Act, and that the Notes and any interest therein may not be offered or sold except as permitted in the following sentence. We agree, on our own behalf and on behalf of any accounts for which we are acting as hereinafter stated, that if we should sell the Notes or any interest therein, we will do so only (A) to the Company or any subsidiary thereof, (B) in accordance with Rule 144A under the Securities Act to a “qualified institutional buyer” (as defined therein), (C) to an institutional “accredited investor” (as defined below) that, prior to such transfer, furnishes (or has furnished on its behalf by a U.S. broker-dealer) to you and to the Company a signed letter substantially in the form of

 

G-1


this letter and, if such transfer is in respect of a principal amount of Notes, at the time of transfer of less than $250,000, an Opinion of Counsel in form reasonably acceptable to the Company to the effect that such transfer is in compliance with the Securities Act, (D) outside the United States in accordance with Rule 904 of Regulation S under the Securities Act, (E) pursuant to the provisions of Rule 144 under the Securities Act or (F) pursuant to an effective registration statement under the Securities Act, and we further agree to provide to any Person purchasing the Definitive Note or beneficial interest in a Global Note from us in a transaction meeting the requirements of clauses (A) through (E) of this paragraph a notice advising such purchaser that resales thereof are restricted as stated herein.

3. We understand that, on any proposed resale of the Notes or beneficial interest therein, we will be required to furnish to you and the Company such certifications, legal opinions and other information as you and the Company may reasonably require to confirm that the proposed sale complies with the foregoing restrictions. We further understand that the Notes purchased by us will bear a legend to the foregoing effect.

4. We are an institutional “accredited investor” (as defined in Rule 501(a)(1), (2), (3) or (7) of Regulation D under the Securities Act) and have such knowledge and experience in financial and business matters as to be capable of evaluating the merits and risks of our investment in the Notes, and we and any accounts for which we are acting are each able to bear the economic risk of our or its investment.

5. We are acquiring the Notes or beneficial interest therein purchased by us for our own account or for one or more accounts (each of which is an institutional “accredited investor”) as to each of which we exercise sole investment discretion.

You and the Company are entitled to rely upon this letter and are irrevocably authorized to produce this letter or a copy hereof to any interested party in any administrative or legal proceedings or official inquiry with respect to the matters covered hereby.

 

     

[Insert Name of Accredited Investor]

By:    
Name:  
Title:  

Dated:____________

 

G-2


EXHIBIT H

FORM OF NET SHORT REPRESENTATION

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

The Bank of New York Mellon Trust Company, N.A., as Trustee

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

Venture Global Calcasieu Pass, LLC (the “Company”) and The Bank of New York Mellon Trust Company, N.A., as trustee (the “Trustee”) have heretofore executed an indenture, dated as of August 5, 2021 (as amended, supplemented or otherwise modified, the “Indenture”), providing for the issuance of the Company’s 3.875% Senior Secured Notes due 2029 and 4.125% Senior Secured Notes due 2031 (collectively, the “Notes”). All terms used herein and not otherwise defined shall have the meaning ascribed to such term under the Indenture.

This letter constitutes a Position Representation in connection with a Noteholder Direction delivered pursuant to Section 6.05 of the Indenture, whereby the undersigned, as Directing Holder, represents to each of the Company and the Trustee that [it is] [its beneficial owners are] not Net Short.

 

By:    
  Name: [Holder]
  Title:

 

H-1


EXHIBIT I

COMMON SECURITY AND ACCOUNT AGREEMENT

[Omitted]

Exhibit 10.84

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

 

 

Execution Version

VENTURE GLOBAL CALCASIEU PASS, LLC,

as Issuer,

and

TRANSCAMERON PIPELINE, LLC,

as the Guarantor,

 

 

FIRST SUPPLEMENTAL INDENTURE

Dated as of November 22, 2021

TO THE INDENTURE

Dated as of August 5, 2021

 

 

The Bank of New York Mellon Trust Company, N.A.,

as Trustee

 

 


TABLE OF CONTENTS

 

         Page  
ARTICLE 1 INTERPRETATION      2  

Section 1.01

 

To Be Read With the Base Indenture

     2  

Section 1.02

 

Capitalized Terms

     2  
ARTICLE 2 ADDITIONAL NOTES      2  

Section 2.01

 

The Additional Notes

     2  

Section 2.02

 

Maturity Date

     2  

Section 2.03

 

Form; Payment of Interest

     2  

Section 2.04

 

Execution and Authentication of the 2033 Notes

     3  
ARTICLE 3 REDEMPTION; AMENDMENTS TO THE INDENTURE      3  

Section 3.01

 

Redemption

     3  

Section 3.02

 

Changes to the Base Indenture

     5  
ARTICLE 4 SECURITY DOCUMENTS      5  

Section 4.01

 

Security Documents

     5  
ARTICLE 5 MISCELLANEOUS      6  

Section 5.01

 

Ratification of the Indenture

     6  

Section 5.02

 

Governing Law

     6  

Section 5.03

 

Counterpart Originals

     6  

Section 5.04

 

Table of Contents, Headings, etc.

     6  

Section 5.05

 

The Trustee

     6  

EXHIBITS

 

Exhibit A-1

   FORM OF NOTE

Exhibit A-2

   FORM OF REGULATION S TEMPORARY GLOBAL NOTE

 

i


FIRST SUPPLEMENTAL INDENTURE dated as of November 22, 2021 (the “First Supplemental Indenture”) between Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Company”), TransCameron Pipeline, LLC (the “Guarantor”) and The Bank of New York Mellon Trust Company, N.A., as Trustee under the Indenture referred to below (the “Trustee”).

WHEREAS, the Company, the Guarantor and the Trustee previously have entered into an indenture, dated as of August 5, 2021 (the “Base Indenture”, as supplemented by this First Supplemental Indenture, and any further amendments or supplements thereto, the “Indenture”), providing for the issuance of 3.875% Senior Secured Notes due 2029 and 4.125% Senior Secured Notes due 2031 (collectively, the “Original Notes”);

WHEREAS, pursuant to Section 9.01(12) of the Base Indenture, the Company, the Guarantor and the Trustee may, without the consent of Holders of the outstanding Original Notes, enter into one or more indentures supplemental to the Base Indenture to provide for the issuance of Additional Notes in accordance with Section 2.01(d) and Exhibit F thereof;

WHEREAS, the Base Indenture provides that Additional Notes may be issued as provided in Exhibit F thereof, including that the terms and conditions of any Additional Notes shall be established in one or more Supplemental Indentures approved pursuant to a Board Resolution;

WHEREAS, pursuant to a Board Resolution dated as of November 16, 2021, the Company has authorized the issuance of Additional Notes of $1,250,000,000 aggregate principal amount of its 3.875% Senior Secured Notes due 2033 (the “2033 Notes”);

WHEREAS, pursuant to Section 2.01(d) of the Base Indenture and Exhibit F thereof, the Company wishes to provide for the issuance of the 2033 Notes, the form, terms and conditions thereof to be set forth as provided in this First Supplemental Indenture;

WHEREAS, the Company has requested that the Trustee join in the execution of this First Supplemental Indenture and has delivered to the Trustee and Officer’s Certificate and an Opinion of Counsel pursuant to Sections 7.02, 9.01, 9.07, 13.04 and 13.05 of the Indenture; and

WHEREAS, all things necessary to make this First Supplemental Indenture a valid agreement of the parties and a valid supplement to the Base Indenture have been done.

NOW, THEREFORE, for and in consideration of the premises and the mutual covenants contained herein and in the Indenture and for other good and valuable consideration, the receipt and sufficiency of which are herein acknowledged, the Company, the Guarantor and the Trustee hereby agree, for the equal and ratable benefit of all Holders, as follows:

 

1


ARTICLE 1

INTERPRETATION

Section 1.01 To Be Read With the Base Indenture.

This First Supplemental Indenture is supplemental to the Base Indenture, and the Base Indenture and this First Supplemental Indenture shall hereafter be read together and shall have effect, so far as practicable, with respect to the 2033 Notes as if all the provisions of the Base Indenture and this First Supplemental Indenture were contained in one instrument.

Section 1.02 Capitalized Terms.

All capitalized terms used but not defined herein shall have the meanings ascribed to such terms in the Base Indenture.

ARTICLE 2

ADDITIONAL NOTES

Section 2.01 The Additional Notes

(a) Pursuant to Section 2.01(d) and Exhibit F of the Base Indenture, the Company hereby creates and issues a series of Notes designated as “3.875% Senior Secured Notes due 2033,” initially limited in aggregate principal amount to $1,250,000,000; provided that the Company may, at any time and from time to time, create and issue additional 2033 Notes in an unlimited principal amount which will be part of the same series as the 2033 Notes and which will have the same terms (except for the issue date, issue price and, in some cases, the first Interest Payment Date) as the 2033 Notes. The 2033 Notes will have the same terms as the Original Notes other than as provided in this First Supplemental Indenture. All 2033 Notes issued under the Indenture will, once issued, be considered Notes for all purposes thereunder and will be subject to and take the benefit of all the terms, conditions and provisions of the Indenture.

(b) The authorized minimum denominations of 2033 Notes shall be $2,000 or integral multiples of $1,000 in excess thereof.

Section 2.02 Maturity Date

The maturity date of the 2033 Notes is November 1, 2033.

Section 2.03 Form; Payment of Interest

(a) With respect to the 2033 Notes, the Notes shall be substantially in the form set forth on Exhibit A-1 or Exhibit A-2 to this First Supplemental Indenture, which is hereby incorporated into this First Supplemental Indenture. The 2033 Notes shall be issuable only in fully registered form, without coupons, and will initially be registered in the name of the Depositary, or its nominee who is hereby designated as “Depositary” under the Base Indenture.

 

2


(b) The Company will pay interest on the 2033 Notes semi-annually in arrears on November 1 and May 1 of each year, or if any such day is not a Business Day, on the next succeeding Business Day. Interest on the 2033 Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from November 22, 2021. The first Interest Payment Date with respect to the 2033 Notes shall be May 1, 2022.

Section 2.04 Execution and Authentication of the 2033 Notes

As provided in and pursuant to Section 2.02 of the Base Indenture, the Trustee shall, pursuant to an Authentication Order, authenticate the 2033 Notes.

ARTICLE 3

REDEMPTION; AMENDMENTS TO THE INDENTURE

Section 3.01 Redemption.

The following redemption provisions shall apply to the 2033 Notes:

Optional Redemption.

At any time or from time to time prior to May 1, 2033 (the “2033 Call Date”), the Company may, at its option, redeem all or a part of the 2033 Notes at a redemption price equal to the 2033 Make-Whole Price plus accrued and unpaid interest on such 2033 Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

2033 Make-Whole Price” with respect to any 2033 Notes to be redeemed, means an amount equal to the greater of:

 

  (1)

100% of the principal amount of such 2033 Notes, without any premium, penalty or charge; and

 

  (2)

an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2033 Call Date (assuming the principal amount is scheduled to be paid on the 2033 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate plus 50 basis points.

At any time on or after the 2033 Call Date, the Company may, at its option, redeem all or a part of the 2033 Notes, at a redemption price equal to 100% of the principal amount of the 2033 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

 

3


The notice of redemption with respect to the foregoing redemption need not set forth the 2033 Make-Whole Price, but only the manner of calculation thereof. The Company will determine the redemption price (including any 2033 Make-Whole Price) and will notify the Trustee of the redemption price (including any 2033 Make-Whole Price) with respect to any redemption promptly, and the Trustee shall not be responsible for such calculation or determination.

Treasury Rate” means the yield to maturity at the time of computation of United States Treasury securities with a constant maturity (as compiled and published in the most recent Federal Reserve Statistical Release H.15 (519) which has become publicly available at least two Business Days (but not more than five Business Days) prior to the relevant redemption date (or, if such Statistical Release is not so published or available, any publicly available source of similar market data selected by the Company in good faith)) most nearly equal to the period from the redemption date to the 2033 Call Date on which the principal of the 2033 Notes being redeemed will be paid in full; provided, however, that if the period from the redemption date to such 2033 Call Date is not equal to the constant maturity of a United States Treasury security for which a weekly average yield is given, the Treasury Rate shall be obtained by linear interpolation (calculated to the nearest one-twelfth of a year) from the weekly average yields of United States Treasury securities for which such yields are given, except that if the period from the redemption date to such 2033 Call Date is less than one year, the weekly average yield on actually traded United States Treasury securities adjusted to a constant maturity of one year shall be used.”

In the event the Company elects to redeem the 2033 Notes as provided above, any such redemption shall comply with Sections 3.01 through Section 3.06 of the Base Indenture.

 

4


Section 3.02 Changes to the Base Indenture.

Section 4.03 of the Base Indenture shall apply to the 2033 Notes; provided that the following clause (c) shall apply to the 2033 Notes and any Additional Notes issued pursuant to the Indenture subsequent to the date hereof in lieu of clause (c) of Section 4.03 of the Base Indenture.

“(c) So long as any of the Notes are outstanding, the Company will furnish or cause to be furnished to the Trustee (a) within 60 days following the end of the first three fiscal quarters of each fiscal year, consolidated unaudited statements of income of each Obligor for such period and for the period from the beginning of the respective fiscal year to the end of such period and consolidated unaudited statements of cash flow of each Obligor for the period from the beginning of the respective fiscal year to the end of such period, setting forth in each case in comparative form the corresponding figures for the corresponding period in the preceding fiscal year, and the related balance sheet as of the end of such period, setting forth in comparative form the corresponding figures as of the end of the prior fiscal year and (b) within 120 days after the end of each fiscal year, its consolidated annual financial statements, audited by the Independent Accountants, in each case prepared in accordance with GAAP, subject, in the case of a quarterly financial statement, to the absence of notes and normal year-end audit adjustments.”

ARTICLE 4

SECURITY DOCUMENTS

Section 4.01 Security Documents.

(a) The 2033 Notes, upon issuance and the execution and delivery of the Accession Agreement, will be Senior Debt for purposes of the CSAA and the Security Documents. The Trustee shall be the Senior Creditor Group Representative for the 2033 Notes. The Holders of the 2033 Notes shall be Senior Noteholders.

(b) Upon the execution and delivery of the Amended and Restated Senior Creditor Group Representative Accession Agreement (which document shall be substantially in the form attached as Schedule D -1 to the CSAA (the “A&R Accession Agreement”)), each Holder of the 2033 Notes, by its acceptance of the 2033 Notes, instructs and directs the Trustee to execute and deliver the A&R Accession Agreement, to which the Trustee and the Collateral Agent will be a party on the date hereof, the 2033 Notes will constitute Additional Senior Debt (as defined in the A&R Accession Agreement) and Senior Debt Obligations that is pari passu with all other Senior Debt Obligations and will be secured by the Collateral equally and ratably with all the other Senior Debt Obligations.

(c) Each Holder of the 2033 Notes appoints the Trustee as Senior Creditor Group Representative of the Holders hereunder for purposes of the A&R Accession Agreement and each Finance Document to which the Trustee is party on behalf of such Holders.

 

5


ARTICLE 5

MISCELLANEOUS

Section 5.01 Ratification of the Indenture.

This First Supplemental Indenture is a supplement to the Base Indenture. The Base Indenture as supplemented by this First Supplemental Indenture is in all respects ratified and confirmed, and the Base Indenture and this First Supplemental Indenture shall together constitute one and the same instrument.

Section 5.02 Governing Law.

THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THIS FIRST SUPPLEMENTAL INDENTURE, THE 2033 NOTES AND ANY NOTE GUARANTEES RELATED TO THE 2033 NOTES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

Section 5.03 Counterpart Originals.

The parties may sign any number of copies of this First Supplemental Indenture. Each signed copy will be an original, but all of them together represent the same agreement. The exchange of copies of this First Supplemental Indenture and of signature pages by facsimile or electronic format (i.e., “pdf” or “tif”) transmission shall constitute effective execution and delivery of this First Supplemental Indenture as to the parties hereto and may be used in lieu of the original First Supplemental Indenture for all purposes. Signatures of the parties hereto transmitted by facsimile or electronic format (i.e., “pdf” or “tif”) shall be deemed to be their original signatures for all purposes. Delivery of an executed First Supplemental Indenture by one party to any other party may be made by facsimile, electronic mail (including any electronic signature complying with the New York Electronic Signatures and Records Act (N.Y. State Tech. §§ 301-309), as amended from time to time, or other applicable law), including DocuSign, or other transmission method, and the parties hereto agree that any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

Section 5.04 Table of Contents, Headings, etc.

The Table of Contents and Headings of the Articles and Sections of this First Supplemental Indenture have been inserted for convenience of reference only, are not to be considered a part of this Indenture and will in no way modify or restrict any of the terms or provisions hereof and will not affect the construction hereof.

Section 5.05 The Trustee.

The recitals contained herein shall be taken as statements of the Company, and the Trustee assumes no responsibility for their correctness. The Trustee makes no representations as to the validity or sufficiency of this First Supplemental Indenture. The Trustee shall not be accountable for the use or application by the Company of the 2033 Notes or the proceeds thereof.

[Signatures on following page]

 

6


SIGNATURES

 

Dated as of November 22, 2021

 

VENTURE GLOBAL CALCASIEU PASS, LLC
By:   /s/ Leah Woodward
Name:   Leah Woodward
Title:   Treasurer
TRANSCAMERON PIPELINE, LLC
By:   /s/ Leah Woodward
Name:   Leah Woodward
Title:   Treasurer
THE BANK OF NEW YORK MELLON, TRUST
COMPANY, N.A., as Trustee
By:   /s/ Shannon Matthews
Name:   Shannon Matthews
Title:   Vice President

[Signature page to Indenture]


EXHIBIT A-1

[Face of Note]

CUSIP: 92328MAC7

ISIN: US92328MAC73

3.875% Senior Secured Notes due 2033

 

No.    

   $     

VENTURE GLOBAL CALCASIEU PASS, LLC

promises to pay to       or registered assigns, the principal sum of                    DOLLARS on November 1, 2033.

Interest Payment Dates: November 1 and May 1, commencing May 1, 2022

Record Dates: October 15 and April 15


Dated: November 22, 2021

 

VENTURE GLOBAL CALCASIEU PASS, LLC
By:    
Name:  
Title:  

 

This is one of the Notes referred to in the within-mentioned Indenture:
THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee
By:    
    Authorized Signatory


[Back of Note]

3.875% Senior Secured Notes due 2033

[Insert the Global Note Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Private Placement Legend, if applicable pursuant to the provisions of the Indenture]

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Company”), promises to pay interest on the principal amount of this Note at 3.875% per annum from November 22, 2021 until maturity. The Company will pay interest semi-annually in arrears on November 1 and May 1 of each year, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from the date of issuance; provided that if there is no existing Unmatured Event of Default or Event of Default in the payment of interest, and if this Note is authenticated between a record date referred to on the face hereof and the next succeeding Interest Payment Date, interest shall accrue from such next succeeding Interest Payment Date; provided further that the first Interest Payment Date shall be May 1, 2022. The Company will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue principal and premium, if any, from time to time on demand at a rate that is 0.50% per annum in excess of the rate then in effect to the extent lawful; it will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue installments of interest (without regard to any applicable grace periods) from time to time on demand at the rate equal to 0.50% per annum in excess of the then applicable interest rate on the Notes to the extent lawful. Interest will be computed on the basis of a 360-day year of twelve 30-day months.

(2) METHOD OF PAYMENT. The Company will pay interest on the Notes (except defaulted interest) to the Persons who are registered Holders of Notes at the close of business on the October 15 or April 15 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium and interest at the office or agency of the Paying Agent or Registrar maintained for such purpose within or without the City and State of New York, or, at the option of the Company, payment of interest may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that payment by wire transfer of immediately available funds will be required with respect to principal of and interest, premium on, all Global Notes and all other Notes the Holders of which will have provided wire transfer instructions to the Company or the Paying Agent. Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.


(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Company may change any Paying Agent or Registrar without notice to any Holder. The Company or any of its Subsidiaries may act in any such capacity.

(4) INDENTURE AND SECURITY DOCUMENTS. The Company issued the Notes under an Indenture dated as of August 5, 2021, as supplemented by a first supplement indenture dated November 22, 2021 (the “Indenture”) among the Company, the Guarantor and the Trustee. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are secured obligations of the Company. The Notes are secured by a pledge of Collateral (as defined in the Indenture) pursuant to the Security Documents referred to in the Indenture. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

At any time or from time to time prior to May 1, 2033 (the “2033 Call Date”), the Company may, at its option, redeem all or a part of the 2033 Notes at a redemption price equal to the 2033 Make-Whole Price plus accrued and unpaid interest on such 2033 Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

2033 Make-Whole Price” with respect to any 2033 Notes to be redeemed, means an amount equal to the greater of:

(1) 100% of the principal amount of such 2033 Notes, without any premium, penalty or charge; and

(2) an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2033 Call Date (assuming the principal amount is scheduled to be paid on the 2033 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate (as defined below) plus 50 basis points.

At any time on or after the 2033 Call Date, the Company may, at its option, redeem all or a part of the 2033 Notes, at a redemption price equal to 100% of the principal amount of the 2033 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).


Treasury Rate” means the yield to maturity at the time of computation of United States Treasury securities with a constant maturity (as compiled and published in the most recent Federal Reserve Statistical Release H.15 (519) which has become publicly available at least two Business Days (but not more than five Business Days) prior to the relevant redemption date (or, if such Statistical Release is not so published or available, any publicly available source of similar market data selected by the Company in good faith)) most nearly equal to the period from the redemption date to the 2033 Call Date on which the principal of the 2033 Notes being redeemed will be paid in full; provided, however, that if the period from the redemption date to such 2033 Call Date is not equal to the constant maturity of a United States Treasury security for which a weekly average yield is given, the Treasury Rate shall be obtained by linear interpolation (calculated to the nearest one-twelfth of a year) from the weekly average yields of United States Treasury securities for which such yields are given, except that if the period from the redemption date to such 2033 Call Date is less than one year, the weekly average yield on actually traded United States Treasury securities adjusted to a constant maturity of one year shall be used.

The notice of redemption with respect to the foregoing redemption need not set forth the 2033 Make-Whole Price, but only the manner of calculation thereof. The Company will determine the redemption price (including any 2033 Make-Whole Price) and will notify the Trustee of the redemption price (including any 2033 Make-Whole Price) with respect to any redemption promptly, and the Trustee shall not be responsible for such calculation or determination.

(6) MANDATORY REDEMPTION.

The Company is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control, the Company will make an offer (a “Change of Control Offer”) of payment (a “Change of Control Payment”) to each Holder to repurchase all or any part (equal to $2,000 and integral multiples of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash equal to not less than 101% of the aggregate principal amount of Notes repurchased plus accrued and unpaid interest if any, to the date of repurchase (the “Change of Control Payment Date,” which date will be no earlier than the date of the corresponding Change of Control). No later than 30 days following any Change of Control, the Company will deliver a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Company will be required to make an Asset Sale Offer, Excess Loss Proceeds Offer, PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer to the extent provided in Sections 4.12, 4.19, 4.20 and 4.21, respectively, of the Indenture.

(8) NOTICE OF REDEMPTION. Notice of redemption will be mailed at least 10 days but not more than 60 days before the redemption date to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes or a satisfaction or discharge of the Indenture. Notes in denominations larger than $2,000 may be redeemed in part but only in whole multiples of $1,000 in excess thereof, unless all of the Notes held by a Holder are to be redeemed.


(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form without coupons in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Company may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Company need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Company need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the corresponding Interest Payment Date.

(10) PERSONS DEEMED OWNERS. The registered Holder of a Note may be treated as its owner for all purposes.

(11) TRUSTEE DEALINGS WITH COMPANY. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Company or its Affiliates, and may otherwise deal with the Company or its Affiliates, as if it were not the Trustee.

(12) NO RECOURSE AGAINST OTHERS. No past, present or future director, manager, officer, employee, incorporator, member, partner, Affiliate or stockholder of the Company or any Guarantor (in each case other than the Company and the Guarantors) or the Sponsor, as such, will have any liability for any obligations of the Company or the Guarantors under the Notes, the Indenture, the Note Guarantees, the Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(13) AUTHENTICATION. This Note will not be valid until authenticated by the manual or electronic signature of the Trustee or an authenticating agent.

(14) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(15) CUSIP NUMBERS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Company has caused CUSIP numbers to be printed on the Notes, and the Trustee may use CUSIP numbers in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

(16) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THIS NOTE AND THE NOTE GUARANTEES.


The Company will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Facsimile No.: [***]

Attention: Treasurer


ASSIGNMENT FORM

 

To assign this Note, fill in the form below:

(I) or (we) assign and transfer this Note  to:                                             
       (Insert assignee’s legal name)

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

(Print or type assignee’s name, address and zip code)

and irrevocably                                                appoint to transfer this Note on the books of the Company. The agent may substitute another to act for him.

Date:       

Your Signature:                     

(Sign exactly as your name appears on the face of this Note)

Signature Guarantee*:        

 

 

* Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, check the appropriate box below:

 

Section 4.12

  

Section 4.17

  

Section 4.19

  

Section 4.20

Section 4.21

        

If you want to elect to have only part of the Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, state the amount you elect to have purchased:

$       

Date:        

 

Your Signature:                 

(Sign exactly as your name appears on the face of this Note)

Tax Identification No:               

Signature Guarantee*:                

 

 

* Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).


SCHEDULE OF EXCHANGES OF INTERESTS IN THE GLOBAL NOTE

The following exchanges of a part of this Global Note for an interest in another Global Note or for a Definitive Note, or exchanges of a part of another Global Note or Definitive Note for an interest in this Global Note, have been made:

 

Date of Exchange

 

Amount of

decrease in

Principal

Amount [at

maturity] of

this Global

Note

 

Amount of

increase in

Principal

Amount [at

maturity] of this

Global Note

  

Principal

Amount [at

maturity] of

this Global

Note following

such decrease

(or increase)

  

Signature of

authorized

officer of

Trustee or

Custodian


EXHIBIT A-2

[Face of Regulation S Temporary Global Note]

CUSIP: U9220MAC7

ISIN: USU9220MAC74

3.875% Senior Secured Notes due 2033

 

No.    

   $        

VENTURE GLOBAL CALCASIEU PASS, LLC

promises to pay to      or registered assigns, the principal sum of                         DOLLARS on November 1, 2033.

Interest Payment Dates: November 1 and May 1, commencing May 1, 2022

Record Dates: October 15 and April 15


Dated: November 22, 2021

 

VENTURE GLOBAL CALCASIEU PASS, LLC
By:    
Name:  
Title:  

 

This is one of the Notes referred to in the within-mentioned Indenture:
THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee
By:    
  Authorized Signatory


[Back of Regulation S Temporary Global Note]

3.875% Senior Secured Notes due 2033

THE RIGHTS ATTACHING TO THIS REGULATION S TEMPORARY GLOBAL NOTE, AND THE CONDITIONS AND PROCEDURES GOVERNING ITS EXCHANGE FOR CERTIFICATED NOTES, ARE AS SPECIFIED IN THE INDENTURE (AS DEFINED HEREIN). NEITHER THE HOLDER NOR THE BENEFICIAL OWNERS OF THIS REGULATION S TEMPORARY GLOBAL NOTE SHALL BE ENTITLED TO RECEIVE PAYMENT OF INTEREST HEREON.

THIS GLOBAL NOTE IS HELD BY THE DEPOSITARY (AS DEFINED IN THE INDENTURE GOVERNING THIS NOTE) OR ITS NOMINEE IN CUSTODY FOR THE BENEFIT OF THE BENEFICIAL OWNERS HEREOF, AND IS NOT TRANSFERABLE TO ANY PERSON UNDER ANY CIRCUMSTANCES EXCEPT THAT (1) THE TRUSTEE MAY MAKE SUCH NOTATIONS HEREON AS MAY BE REQUIRED PURSUANT TO SECTION 2.06 OF THE INDENTURE, (2) THIS GLOBAL NOTE MAY BE EXCHANGED IN WHOLE BUT NOT IN PART PURSUANT TO SECTION 2.06(a) OF THE INDENTURE, (3) THIS GLOBAL NOTE MAY BE DELIVERED TO THE TRUSTEE FOR CANCELLATION PURSUANT TO SECTION 2.11 OF THE INDENTURE AND (4) THIS GLOBAL NOTE MAY BE TRANSFERRED TO A SUCCESSOR DEPOSITARY WITH THE PRIOR WRITTEN CONSENT OF THE COMPANY.

UNLESS AND UNTIL IT IS EXCHANGED IN WHOLE OR IN PART FOR NOTES IN DEFINITIVE FORM, THIS NOTE MAY NOT BE TRANSFERRED EXCEPT AS A WHOLE BY THE DEPOSITARY TO A NOMINEE OF THE DEPOSITARY OR BY A NOMINEE OF THE DEPOSITARY TO THE DEPOSITARY OR ANOTHER NOMINEE OF THE DEPOSITARY OR BY THE DEPOSITARY OR ANY SUCH NOMINEE TO A SUCCESSOR DEPOSITARY OR A NOMINEE OF SUCH SUCCESSOR DEPOSITARY. UNLESS THIS CERTIFICATE IS PRESENTED BY AN AUTHORIZED REPRESENTATIVE OF THE DEPOSITORY TRUST COMPANY (55 WATER STREET, NEW YORK, NEW YORK) (“DTC”), TO THE COMPANY OR ITS AGENT FOR REGISTRATION OF TRANSFER, EXCHANGE OR PAYMENT, AND ANY CERTIFICATE ISSUED IS REGISTERED IN THE NAME OF CEDE & CO. OR SUCH OTHER NAME AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC (AND ANY PAYMENT IS MADE TO CEDE & CO. OR SUCH OTHER ENTITY AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC), ANY TRANSFER, PLEDGE OR OTHER USE HEREOF FOR VALUE OR OTHERWISE BY OR TO ANY PERSON IS WRONGFUL INASMUCH AS THE REGISTERED OWNER HEREOF, CEDE & CO., HAS AN INTEREST HEREIN.

THIS NOTE HAS NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), AND MAY NOT BE OFFERED, SOLD, PLEDGED OR OTHERWISE TRANSFERRED EXCEPT IN ACCORDANCE WITH THE FOLLOWING SENTENCE. BY ITS ACQUISITION HEREOF OR OF A BENEFICIAL INTEREST HEREIN, THE ACQUIRER AGREES FOR THE BENEFIT OF VENTURE GLOBAL CALCASIEU PASS, LLC THAT IT WILL NOT OFFER, SELL, PLEDGE OR OTHERWISE TRANSFER THIS NOTE OR ANY BENEFICIAL INTEREST HEREIN, EXCEPT IN ACCORDANCE WITH THE SECURITIES ACT AND ANY APPLICABLE SECURITIES LAWS OF ANY


STATE OF THE UNITED STATES AND ONLY (A) TO VENTURE GLOBAL CALCASIEU PASS, LLC, (B) PURSUANT TO A REGISTRATION STATEMENT WHICH HAS BECOME EFFECTIVE UNDER THE SECURITIES ACT, (C) TO A QUALIFIED INSTITUTIONAL BUYER IN COMPLIANCE WITH RULE 144A UNDER THE SECURITIES ACT, (D) IN AN OFFSHORE TRANSACTION IN COMPLIANCE WITH RULE 904 OF REGULATION S UNDER THE SECURITIES ACT, (E) TO AN INSTITUTIONAL “ ACCREDITED INVESTOR” WITHIN THE MEANING OF RULE 501(a)(1), (2), (3) OR (7) UNDER THE SECURITIES ACT THAT IS NOT A QUALIFIED INSTITUTIONAL BUYER AND THAT IS PURCHASING FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF ANOTHER INSTITUTIONAL ACCREDITED INVESTOR, IN EACH CASE IN A MINIMUM PRINCIPAL AMOUNT OF THE SECURITIES OF $250,000, FOR INVESTMENT PURPOSES AND NOT WITH A VIEW TO OR FOR OFFER OR SALE IN CONNECTION WITH ANY DISTRIBUTION IN VIOLATION OF THE SECURITIES ACT OR (F) PURSUANT TO AN EXEMPTION FROM REGISTRATION PROVIDED BY RULE 144 UNDER THE SECURITIES ACT OR ANY OTHER AVAILABLE EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT. PRIOR TO THE REGISTRATION OF ANY TRANSFER IN ACCORDANCE WITH CLAUSES (C), (D) OR (E) ABOVE, A DULY COMPLETED AND SIGNED CERTIFICATE (THE FORM OF WHICH MAY BE OBTAINED FROM THE TRUSTEE) MUST BE DELIVERED TO THE TRUSTEE. PRIOR TO THE REGISTRATION OF ANY TRANSFER IN ACCORDANCE WITH (F) ABOVE, VENTURE GLOBAL CALCASIEU PASS, LLC RESERVES THE RIGHT TO REQUIRE THE DELIVERY OF SUCH LEGAL OPINIONS, CERTIFICATIONS OR OTHER EVIDENCE AS MAY REASONABLY BE REQUIRED IN ORDER TO DETERMINE THAT THE PROPOSED TRANSFER IS BEING MADE IN COMPLIANCE WITH THE SECURITIES ACT AND APPLICABLE STATE SECURITIES LAWS. NO REPRESENTATION IS MADE AS TO THE AVAILABILITY OF ANY RULE 144 EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT.

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Company”), promises to pay interest on the principal amount of this Note at 3.875% per annum from November 22, 2021 until maturity. The Company will pay interest semi-annually in arrears on November 1 and May 1 of each year, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from the date of issuance; provided that if there is no existing Unmatured Event of Default or Event of Default in the payment of interest, and if this Note is authenticated between a record date referred to on the face hereof and the next succeeding Interest Payment Date, interest shall accrue from such next succeeding Interest Payment Date; provided further that the first Interest Payment Date shall be May 1, 2022. The Company will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue principal and premium, if any, from time to time on demand at a rate that is 0.50% per annum in excess of the rate then in effect to the extent lawful; it will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue installments of interest (without regard to any applicable grace periods) from time to time on demand at the rate equal to 0.50% per annum in excess of the then applicable interest rate on the Notes to the extent lawful. Interest will be computed on the basis of a 360-day year of twelve 30-day months.


Until this Regulation S Temporary Global Note is exchanged for one or more Regulation S Permanent Global Notes, the Holder hereof shall not be entitled to receive payments of interest hereon; until so exchanged in full, this Regulation S Temporary Global Note shall in all other respects be entitled to the same benefits as other Notes under the Indenture.

(2) METHOD OF PAYMENT. The Company will pay interest on the Notes (except defaulted interest) to the Persons who are registered Holders of Notes at the close of business on the October 15 or April 15 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium and interest at the office or agency of the Paying Agent or Registrar maintained for such purpose within or without the City and State of New York, or, at the option of the Company, payment of interest may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that payment by wire transfer of immediately available funds will be required with respect to principal of and interest, premium on, all Global Notes and all other Notes the Holders of which will have provided wire transfer instructions to the Company or the Paying Agent. Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Company may change any Paying Agent or Registrar without notice to any Holder. The Company or any of its Subsidiaries may act in any such capacity.

(4) INDENTURE AND SECURITY DOCUMENTS. The Company issued the Notes under an Indenture dated as of August 5, 2021, as supplemented by a first supplement indenture dated November 22, 2021 (the “Indenture”) among the Company, the Guarantor and the Trustee. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are secured obligations of the Company. The Notes are secured by a pledge of Collateral (as defined in the Indenture) pursuant to the Security Documents referred to in the Indenture. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

At any time or from time to time prior to May 1, 2033 (the “2033 Call Date”), the Company may, at its option, redeem all or a part of the 2033 Notes at a redemption price equal to the 2033 Make-Whole Price plus accrued and unpaid interest on such Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).


2033 Make-Whole Price” with respect to any 2033 Notes to be redeemed, means an amount equal to the greater of:

(1) 100% of the principal amount of such 2033 Notes, without any premium, penalty or charge; and

(2) an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2033 Call Date (assuming the principal amount is scheduled to be paid on the 2033 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate (as defined below) plus 50 basis points.

At any time on or after the 2033 Call Date, the Company may, at its option, redeem all or a part of the 2033 Notes, at a redemption price equal to 100% of the principal amount of the 2033 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

Treasury Rate” means the yield to maturity at the time of computation of United States Treasury securities with a constant maturity (as compiled and published in the most recent Federal Reserve Statistical Release H.15 (519) which has become publicly available at least two Business Days (but not more than five Business Days) prior to the relevant redemption date (or, if such Statistical Release is not so published or available, any publicly available source of similar market data selected by the Company in good faith)) most nearly equal to the period from the redemption date to the 2033 Call Date on which the principal of the 2033 Notes being redeemed will be paid in full; provided, however, that if the period from the redemption date to such 2033 Call Date is not equal to the constant maturity of a United States Treasury security for which a weekly average yield is given, the Treasury Rate shall be obtained by linear interpolation (calculated to the nearest one-twelfth of a year) from the weekly average yields of United States Treasury securities for which such yields are given, except that if the period from the redemption date to such 2033 Call Date is less than one year, the weekly average yield on actually traded United States Treasury securities adjusted to a constant maturity of one year shall be used.

The notice of redemption with respect to the foregoing redemption need not set forth the 2033 Make-Whole Price, but only the manner of calculation thereof. The Company will determine the redemption price (including any 2033 Make-Whole Price) and will notify the Trustee of the redemption price (including any 2033 Make-Whole Price) with respect to any redemption promptly, and the Trustee shall not be responsible for such calculation or determination.


(6) MANDATORY REDEMPTION.

The Company is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control, the Company will make an offer (a “Change of Control Offer”) of payment (a “Change of Control Payment”) to each Holder to repurchase all or any part (equal to $2,000 and integral multiples of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash equal to not less than 101% of the aggregate principal amount of Notes repurchased plus accrued and unpaid interest if any, to the date of repurchase (the “Change of Control Payment Date,” which date will be no earlier than the date of the corresponding Change of Control). No later than 30 days following any Change of Control, the Company will deliver a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Company will be required to make an Asset Sale Offer, Excess Loss Proceeds Offer, PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer to the extent provided in Sections 4.12, 4.19, 4.20 and 4.21, respectively, of the Indenture.

(8) NOTICE OF REDEMPTION. Notice of redemption will be mailed at least 10 days but not more than 60 days before the redemption date to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes or a satisfaction or discharge of the Indenture. Notes in denominations larger than $2,000 may be redeemed in part but only in whole multiples of $1,000 in excess thereof, unless all of the Notes held by a Holder are to be redeemed.

(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form without coupons in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Company may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Company need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Company need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the corresponding Interest Payment Date.

This Regulation S Temporary Global Note is exchangeable in whole or in part for one or more Global Notes only (i) on or after the termination of the 40-day distribution compliance period (as defined in Regulation S) and (ii) upon presentation of certificates (accompanied by an Opinion of Counsel, if applicable) required by Article 2 of the Indenture. Upon exchange of this Regulation S Temporary Global Note for one or more Global Notes, the Trustee shall cancel this Regulation S Temporary Global Note.


(10) PERSONS DEEMED OWNERS. The registered Holder of a Note may be treated as its owner for all purposes.

(11) TRUSTEE DEALINGS WITH COMPANY. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Company or its Affiliates, and may otherwise deal with the Company or its Affiliates, as if it were not the Trustee.

(12) NO RECOURSE AGAINST OTHERS. No past, present or future director, manager, officer, employee, incorporator, member, partner, Affiliate or stockholder of the Company or any Guarantor (in each case other than the Company and the Guarantors) or the Sponsor, as such, will have any liability for any obligations of the Company or the Guarantors under the Notes, the Indenture, the Note Guarantees, the Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(13) AUTHENTICATION. This Note will not be valid until authenticated by the manual or electronic signature of the Trustee or an authenticating agent.

(14) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(15) CUSIP NUMBERS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Company has caused CUSIP numbers to be printed on the Notes, and the Trustee may use CUSIP numbers in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

(16) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THIS NOTE AND THE NOTE GUARANTEES.

The Company will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Facsimile No.: [***]

Attention: Treasurer


ASSIGNMENT FORM

 

To assign this Note, fill in the form below:

(I) or (we) assign and transfer this Note  to:                                             
       (Insert assignee’s legal name)

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

(Print or type assignee’s name, address and zip code)

and irrevocably                                                appoint to transfer this Note on the books of the Company. The agent may substitute another to act for him.

Date:       

Your Signature:                     

(Sign exactly as your name appears on the face of this Note)

Signature Guarantee*:        

 

 

* Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, check the appropriate box below:

 

Section 4.12

  

Section 4.17

  

Section 4.19

  

Section 4.20

Section 4.21

        

If you want to elect to have only part of the Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, state the amount you elect to have purchased:

$       

Date:        

 

Your Signature:               

(Sign exactly as your name appears on the face of this Note)

Tax Identification No:             

Signature Guarantee*:                

 

 

* Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).


SCHEDULE OF EXCHANGES OF INTERESTS IN THE REGULATIONS

TEMPORARY GLOBAL NOTE

The following exchanges of a part of this Regulation S Temporary Global Note for an interest in another Global Note, or exchanges of a part of another other Restricted Global Note for an interest in this Regulation S Temporary Global Note, have been made:

 

Date of Exchange

 

Amount of

decrease in

Principal

Amount [at

maturity] of

this Global

Note

 

Amount of

increase in

Principal

Amount [at

maturity] of this

Global Note

  

Principal

Amount [at

maturity] of

this Global

Note following

such decrease

(or increase)

  

Signature of

authorized

officer of

Trustee or

Custodian

Exhibit 10.85

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

 

 

VENTURE GLOBAL CALCASIEU PASS, LLC,

as Issuer,

and

TRANSCAMERON PIPELINE, LLC,

as the Guarantor,

 

 

SECOND SUPPLEMENTAL INDENTURE

Dated as of January 13, 2023

TO THE INDENTURE

Dated as of August 5, 2021

 

 

The Bank of New York Mellon Trust Company, N.A.,

as Trustee

 

 


TABLE OF CONTENTS

 

          Page  

ARTICLE 1 INTERPRETATION

     2  

Section 1.01

   To Be Read With the Base Indenture      2  

Section 1.02

   Capitalized Terms      2  

ARTICLE 2 ADDITIONAL NOTES

     2  

Section 2.01

   The Additional Notes      2  

Section 2.02

   Maturity Date, Notes Issue Date, Indenture Payment Date, Interest Payment Date      3  

Section 2.03

   Form; Payment of Interest      3  

Section 2.04

   Execution and Authentication of the 2030 Notes      3  

ARTICLE 3 REDEMPTION; AMENDMENTS TO THE INDENTURE

     3  

Section 3.01

   Redemption      3  

Section 3.02

   Changes to the Base Indenture      5  

ARTICLE 4 SECURITY DOCUMENTS

     6  

Section 4.01

   Security Documents      6  

ARTICLE 5 MISCELLANEOUS

     7  

Section 5.01

   Ratification of the Indenture      7  

Section 5.02

   Corresponding Amendments      7  

Section 5.03

   Governing Law      7  

Section 5.04

   Counterpart Originals      7  

Section 5.05

   Table of Contents, Headings, etc.      7  

Section 5.06

   The Trustee      8  

EXHIBITS

 

Exhibit A-1

   FORM OF NOTE

Exhibit A-2

   FORM OF REGULATION S TEMPORARY GLOBAL NOTE

 

i


SECOND SUPPLEMENTAL INDENTURE dated as of January 13, 2023 (the “Second Supplemental Indenture”) between Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Company”), TransCameron Pipeline, LLC (the “Guarantor”) and The Bank of New York Mellon Trust Company, N.A., as Trustee under the Indenture referred to below (the “Trustee”).

WHEREAS, the Company, the Guarantor and the Trustee previously have entered into an indenture, dated as of August 5, 2021 (the “Base Indenture”, as supplemented by the First Supplemental Indenture, dated as of November 22, 2021 (the “First Supplemental Indenture”), this Second Supplemental Indenture, and any further amendments or supplements thereto, the “Indenture”), providing for the issuance of 3.875% Senior Secured Notes due 2029, 4.125% Senior Secured Notes due 2031 and 3.875% Senior Secured Notes due 2033 (collectively, the “Existing Notes”);

WHEREAS, pursuant to Section 9.01(12) of the Base Indenture, the Company, the Guarantor and the Trustee may, without the consent of Holders of the outstanding Existing Notes, enter into one or more indentures supplemental to the Base Indenture to provide for the issuance of Additional Notes in accordance with Section 2.01(d) and Exhibit F thereof;

WHEREAS, pursuant to Section 9.01(1) of the Base Indenture, the Company, the Guarantor and the Trustee may, without the consent of Holders of the outstanding Existing Notes, cure any ambiguity, omission, mistake, defect or inconsistency;

WHEREAS, pursuant to Section 9.01(14) of the Base Indenture, the Company, the Guarantor and the Trustee may, without the consent of Holders of the outstanding Existing Notes, change or modify any provision or definition from the CSAA, included or referred to in the Base Indenture, the Note Guarantees or the Notes, as applicable, to the extent such provision or definition is changed or modified in the CSAA either (I) pursuant to Section 9.03 of the Base Indenture or (II) as otherwise permitted under the CSAA;

WHEREAS, the Base Indenture provides that Additional Notes may be issued as provided in Exhibit F thereof, including that the terms and conditions of any Additional Notes shall be established in one or more Supplemental Indentures approved pursuant to a Board Resolution;

WHEREAS, pursuant to a Board Resolution dated as of January 9, 2023, the Company has authorized the issuance of Additional Notes of $1,000,000,000 aggregate principal amount of its 6.250% Senior Secured Notes due 2030 (the “2030 Notes”);

WHEREAS, pursuant to Section 2.01(d) of the Base Indenture and Exhibit F thereof, the Company wishes to provide for the issuance of the 2030 Notes, the form, terms and conditions thereof to be set forth as provided in this Second Supplemental Indenture;

WHEREAS, pursuant to Section 9.01(1) of the Base Indenture, the Company wishes to amend or modify certain definitions in the Base Indenture to cure certain ambiguities;

 

1


WHEREAS, pursuant to Section 9.01(14) of the Base Indenture, the Company wishes to amend and modify certain definitions from the CSAA, included or referred to in the Base Indenture as such definitions have been changed or modified in the CSAA;

WHEREAS, the Company has requested that the Trustee join in the execution of this Second Supplemental Indenture and has delivered to the Trustee an Officer’s Certificate and an Opinion of Counsel pursuant to Sections 7.02, 9.01, 9.07, 13.04 and 13.05 of the Base Indenture; and

WHEREAS, all things necessary to make this Second Supplemental Indenture a valid agreement of the parties and a valid supplement to the Base Indenture have been done.

NOW, THEREFORE, for and in consideration of the premises and the mutual covenants contained herein and in the Indenture and for other good and valuable consideration, the receipt and sufficiency of which are herein acknowledged, the Company, the Guarantor and the Trustee hereby agree, for the equal and ratable benefit of all Holders, as follows:

ARTICLE 1

INTERPRETATION

Section 1.01 To Be Read With the Base Indenture.

This Second Supplemental Indenture is supplemental to the Base Indenture, and the Base Indenture, the First Supplemental Indenture and this Second Supplemental Indenture shall hereafter be read together and shall have effect, so far as practicable, with respect to the 2030 Notes as if all the provisions of the Base Indenture, the First Supplemental Indenture and this Second Supplemental Indenture were contained in one instrument.

Section 1.02 Capitalized Terms.

All capitalized terms used but not defined herein shall have the meanings ascribed to such terms in the Base Indenture.

ARTICLE 2

ADDITIONAL NOTES

Section 2.01 The Additional Notes

(a) Pursuant to Section 2.01(d) and Exhibit F of the Base Indenture, the Company hereby creates and issues a series of Notes designated as “6.250% Senior Secured Notes due 2030,” initially limited in aggregate principal amount to $1,000,000,000; provided that the Company may, at any time and from time to time, create and issue additional 2030 Notes in an unlimited principal amount which will be part of the same series as the 2030 Notes and which will have the same terms (except for the issue date, issue price and, in some cases, the first Interest Payment Date) as the 2030 Notes. The 2030 Notes will have the same terms as the Existing Notes other than as provided in this Second Supplemental Indenture. All 2030 Notes issued under the Indenture will, once issued, be considered Notes for all purposes thereunder and will be subject to and take the benefit of all the terms, conditions and provisions of the Indenture.

 

2


(b) The authorized minimum denominations of 2030 Notes shall be $2,000 or integral multiples of $1,000 in excess thereof.

Section 2.02 Maturity Date, Notes Issue Date, Indenture Payment Date, Interest Payment Date

The maturity date of the 2030 Notes is January 15, 2030. The Notes Issue Date of the 2030 Notes is January 13, 2023. The Indenture Payment Date of the 2030 Notes means payments dates of January 15 and July 15. The Interest Payment Date of the 2030 Notes means payment dates of January 15 and July 15 of each year, commencing on July 15, 2023, or if any such day is not a Business Day, the next succeeding Business Day.

Section 2.03 Form; Payment of Interest

(a) With respect to the 2030 Notes, the Notes shall be substantially in the form set forth on Exhibit A-1 or Exhibit A-2 to this Second Supplemental Indenture, which is hereby incorporated into this Second Supplemental Indenture. The 2030 Notes shall be issuable only in fully registered form, without coupons, and will initially be registered in the name of the Depositary, or its nominee who is hereby designated as “Depositary” under the Base Indenture.

(b) The Company will pay interest on the 2030 Notes semi-annually in arrears on January 15 and July 15 of each year, or if any such day is not a Business Day, on the next succeeding Business Day. Interest on the 2030 Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from January 13, 2023. The first Interest Payment Date with respect to the 2030 Notes shall be July 15, 2023.

Section 2.04 Execution and Authentication of the 2030 Notes

As provided in and pursuant to Section 2.02 of the Base Indenture, the Trustee shall, pursuant to an Authentication Order, authenticate the 2030 Notes.

ARTICLE 3

REDEMPTION; AMENDMENTS TO THE INDENTURE

Section 3.01 Redemption.

The following redemption provisions shall apply to the 2030 Notes:

Optional Redemption.

At any time or from time to time prior to October 15, 2029 (three months prior to the maturity of the 2030 Notes) (the “2030 Call Date”), the Company may, at its option, redeem all or a part of the 2030 Notes at a redemption price equal to the 2030 Make-Whole Price plus accrued and unpaid interest on such 2030 Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

 

3


2030 Make-Whole Price” with respect to any 2030 Notes to be redeemed, means an amount equal to the greater of:

 

  (1)

100% of the principal amount of such 2030 Notes, without any premium, penalty or charge; and

 

  (2)

an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2030 Call Date (assuming the principal amount is scheduled to be paid on the 2030 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate plus 50 basis points.

At any time on or after the 2030 Call Date, the Company may, at its option, redeem all or a part of the 2030 Notes, at a redemption price equal to 100% of the principal amount of the 2030 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

The notice of redemption with respect to the foregoing redemption need not set forth the 2030 Make-Whole Price, but only the manner of calculation thereof. The Company will determine the redemption price (including any 2030 Make-Whole Price) and will notify the Trustee of the redemption price (including any 2030 Make-Whole Price) with respect to any redemption promptly, and the Trustee shall not be responsible for such calculation or determination.

Treasury Rate” means, as of any redemption date, the yield to maturity as of the earlier of (a) such redemption date or (b) the date on which obligations under the indenture are defeased or satisfied and discharged, of United States Treasury securities with a constant maturity (as compiled and published in the most recent Selected Interest Rates (Daily) H.15 which has become publicly available at least two Business Days (but not more than five Business Days) prior to such date (or, if such release is not so published or available, any publicly available source of similar market data selected by the Company in good faith)) most nearly equal to the period from such date to the 2030 Call Date on which the principal of the 2030 Notes being redeemed will be paid in full; provided, however, that if the period from such date to the 2030 Call Date is not equal to the constant maturity of a United States Treasury security for which a weekly average yield is given, the Treasury Rate shall be obtained by linear interpolation (calculated to the nearest one-twelfth of a year) from the weekly average yields of United States Treasury securities for which such yields are given, except that if the period from such date to the 2030 Call Date is less than one year, the weekly average yield on actually traded United States Treasury securities adjusted to a constant maturity of one year shall be used.”

 

4


In the event the Company elects to redeem the 2030 Notes as provided above, any such redemption shall comply with Sections 3.01 through Section 3.06 of the Base Indenture.

Section 3.02 Changes to the Base Indenture.

(a) Pursuant to Section 9.01(14) of the Base Indenture, the Company, the Guarantor and the Trustee agree (in the case of the Trustee, acting upon the request of the Company accompanied by a resolution of its Board of Directors and in reliance upon an Officer’s Certificate and an Opinion of Counsel dated the date hereof), the following definitions in Section 1.01 of the Base Indenture (which are definitions from the CSAA that have been modified pursuant to the terms of the CSAA) shall be modified and replaced to be consistent with such definition in the CSAA by the following new definitions:

“Date Certain” means September 27, 2023 provided that if, on or prior to September 27, 2023, the Borrower certifies to the Intercreditor Agent (and the Independent Engineer reasonably concurs with such certification in writing) that (i) the only remaining condition to the Project Completion Date as of the date of delivery of such certification, other than conditions that can only be satisfied on the Project Completion Date, is the condition specified in Section 14.1(c)(iii) (Conditions to Occurrence of the Project Completion Date – Physical Completion Certificate) of the CSAA and (ii) the Lenders’ Reliability Test has commenced in accordance with the procedures specified in Section 12.11 (Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages) of the CSAA and is reasonably expected to be completed on or prior to December 27, 2023, then for all purposes under this Indenture the “Date Certain” means December 27, 2023.

“Term Loan Availability Period” means the period commencing (solely with respect to the initial advance under the Credit Facility Agreement) on the Credit Facilities Closing Date and (with respect to all other advances of Term Loans) following the utilization in full of both the Closing Date Equity Funding and the initial advance under the Credit Facility Agreement, and ending on the earliest of:

(a) March 31, 2023;

(b) the Project Completion Date;

(c) the date the Term Loan Commitments are fully utilized or of any cancellation or termination of all of the remaining Term Loan Commitments pursuant the Common Terms Agreement; and

(d) the date the Required Lenders terminate their commitments under the Credit Facility Agreement upon the occurrence and during the Continuance of a Loan Facility Event of Default.

 

5


(b) Pursuant to Section 9.01(1) of the Base Indenture, the Company, the Guarantor and the Trustee agree (in the case of the Trustee, acting upon the request of the Company accompanied by a resolution of its Board of Directors and in reliance upon an Officer’s Certificate and an Opinion of Counsel dated the date hereof), the following definitions in Section 1.01 of the Base Indenture shall be modified and replaced to cure any ambiguity by the following new definitions:

“Indenture Payment Date” for the applicable series of Notes issued under this Indenture shall have the meaning specified in this Indenture with respect to the initial series of notes issued under this Indenture and for each other applicable series, the meaning specified in the applicable supplemental indenture pertaining to such series.

“Interest Payment Date” for the applicable series of Notes issued under this Indenture shall have the meaning specified in this Indenture with respect to the initial series of notes issued under this Indenture and for each other applicable series, the meaning specified in the applicable supplemental indenture pertaining to such series, or if any such day is not a Business Day, the next succeeding Business Day.

“Notes Issue Date” for the applicable series of Notes issued under this Indenture shall have the meaning specified in this Indenture with respect to the initial series of notes issued under this Indenture and for each other applicable series, the meaning specified in the applicable supplemental indenture pertaining to such series.

ARTICLE 4

SECURITY DOCUMENTS

Section 4.01 Security Documents.

(a) The 2030 Notes, upon issuance and the execution and delivery of the Accession Agreement, will be Senior Debt for purposes of the CSAA and the Security Documents. The Trustee shall be the Senior Creditor Group Representative for the 2030 Notes. The Holders of the 2030 Notes shall be Senior Noteholders.

(b) Upon the execution and delivery of the Second Amended and Restated Senior Creditor Group Representative Accession Agreement (which document shall be substantially in the form attached as Schedule D-1 to the CSAA (the “A&R Accession Agreement”)), each Holder of the 2030 Notes, by its acceptance of the 2030 Notes, instructs and directs the Trustee to execute and deliver the A&R Accession Agreement, to which the Trustee and the Collateral Agent will be a party on the date hereof, the 2030 Notes will constitute Additional Senior Debt (as defined in the A&R Accession Agreement) and Senior Debt Obligations that is pari passu with all other Senior Debt Obligations and will be secured by the Collateral equally and ratably with all the other Senior Debt Obligations.

(c) Each Holder of the 2030 Notes appoints the Trustee as Senior Creditor Group Representative of the Holders hereunder for purposes of the A&R Accession Agreement and each Finance Document to which the Trustee is party on behalf of such Holders.

 

6


ARTICLE 5

MISCELLANEOUS

Section 5.01 Ratification of the Indenture.

This Second Supplemental Indenture is a supplement to the Base Indenture. The Base Indenture as supplemented by the First Supplemental Indenture and this Second Supplemental Indenture is in all respects ratified and confirmed, and the Base Indenture, the First Supplemental Indenture and this Second Supplemental Indenture shall together constitute one and the same instrument.

Section 5.02 Corresponding Amendments.

With effect on and from the date hereof, each Global Note shall be deemed supplemented, modified and amended in such manner as necessary to make the terms of such Global Note consistent with the terms of the Indenture, as amended by this Second Supplemental Indenture. To the extent of any conflict between the terms of the Notes and the terms of the Indenture, as amended by this Second Supplemental Indenture, the terms of the Indenture, as amended by this Second Supplemental Indenture, shall govern and be controlling.

Section 5.03 Governing Law.

THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THIS SECOND SUPPLEMENTAL INDENTURE, THE 2030 NOTES AND ANY NOTE GUARANTEES RELATED TO THE 2030 NOTES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

Section 5.04 Counterpart Originals.

The parties may sign any number of copies of this Second Supplemental Indenture. Each signed copy will be an original, but all of them together represent the same agreement. The exchange of copies of this Second Supplemental Indenture and of signature pages by facsimile or electronic format (i.e., “pdf” or “tif”) transmission shall constitute effective execution and delivery of this Second Supplemental Indenture as to the parties hereto and may be used in lieu of the original Second Supplemental Indenture for all purposes. Signatures of the parties hereto transmitted by facsimile or electronic format (i.e., “pdf” or “tif”) shall be deemed to be their original signatures for all purposes. Delivery of an executed Second Supplemental Indenture by one party to any other party may be made by facsimile, electronic mail (including any electronic signature complying with the New York Electronic Signatures and Records Act (N.Y. State Tech. §§ 301-309), as amended from time to time, or other applicable law), including DocuSign, or other transmission method, and the parties hereto agree that any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

Section 5.05 Table of Contents, Headings, etc.

The Table of Contents and Headings of the Articles and Sections of this Second Supplemental Indenture have been inserted for convenience of reference only, are not to be considered a part of this Indenture and will in no way modify or restrict any of the terms or provisions hereof and will not affect the construction hereof.

 

7


Section 5.06 The Trustee.

The recitals contained herein shall be taken as statements of the Company, and the Trustee assumes no responsibility for their correctness. The Trustee makes no representations as to the validity or sufficiency of this Second Supplemental Indenture. The Trustee shall not be accountable for the use or application by the Company of the 2030 Notes or the proceeds thereof.

The Trustee accepts the amendments of the Indenture effected by this Second Supplemental Indenture and agrees to execute the trust created by the Indenture as hereby amended, but on the terms and conditions set forth in the Indenture, including the terms and provisions defining and limiting its liabilities and responsibilities in the performance of the trust created by the Indenture as hereby amended. For the avoidance of doubt, the Trustee, by executing this Second Supplemental Indenture in accordance with the terms of the Indenture, does not agree to undertake additional actions nor does it consent to any transaction beyond what is expressly set forth in this Second Supplemental Indenture, and the Trustee reserves all rights and remedies under the Indenture.

[Signatures on following page]

 

8


SIGNATURES

Dated as of January 13, 2023

 

VENTURE GLOBAL CALCASIEU PASS, LLC
By:  

/s/ Leah Woodward

Name:   Leah Woodward
Title:   Treasurer
TRANSCAMERON PIPELINE, LLC
By:  

/s/ Leah Woodward

Name:   Leah Woodward
Title:   Treasurer
THE BANK OF NEW YORK MELLON, TRUST COMPANY, N.A., as Trustee
By:  

/s/ Ann M. Dolezal

Name:   Ann M. Dolezal
Title:   Vice President

 

[Signature page to Second Supplemental Indenture]


EXHIBIT A-1

[Face of Note]

CUSIP: 92328M AE3

ISIN: US92328MAE30

6.250% Senior Secured Notes due 2030

 

No.    

   $      

VENTURE GLOBAL CALCASIEU PASS, LLC

promises to pay to      or registered assigns, the principal sum of                    DOLLARS on January 15, 2030.

Interest Payment Dates: January 15 and July 15, commencing July 15, 2023

Record Dates: January 1 and July 1


Dated: January 13, 2023

 

VENTURE GLOBAL CALCASIEU PASS, LLC
By:  

 

Name:  
Title:  

 

This is one of the Notes referred to in the within-mentioned Indenture:
THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee
By:  

 

  Authorized Signatory


[Back of Note]

6.250% Senior Secured Notes due 2030

[Insert the Global Note Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Private Placement Legend, if applicable pursuant to the provisions of the Indenture]

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Company”), promises to pay interest on the principal amount of this Note at 6.250% per annum from January 13, 2023 until maturity. The Company will pay interest semi-annually in arrears on January 15 and July 15 of each year, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from the date of issuance; provided that if there is no existing Unmatured Event of Default or Event of Default in the payment of interest, and if this Note is authenticated between a record date referred to on the face hereof and the next succeeding Interest Payment Date, interest shall accrue from such next succeeding Interest Payment Date; provided further that the first Interest Payment Date shall be July 15, 2023. The Company will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue principal and premium, if any, from time to time on demand at a rate that is 0.50% per annum in excess of the rate then in effect to the extent lawful; it will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue installments of interest (without regard to any applicable grace periods) from time to time on demand at the rate equal to 0.50% per annum in excess of the then applicable interest rate on the Notes to the extent lawful. Interest will be computed on the basis of a 360-day year of twelve 30-day months.

(2) METHOD OF PAYMENT. The Company will pay interest on the Notes (except defaulted interest) to the Persons who are registered Holders of Notes at the close of business on the January 1 or July 1 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium and interest at the office or agency of the Paying Agent or Registrar maintained for such purpose within or without the City and State of New York, or, at the option of the Company, payment of interest may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that payment by wire transfer of immediately available funds will be required with respect to principal of and interest, premium on, all Global Notes and all other Notes the Holders of which will have provided wire transfer instructions to the Company or the Paying Agent. Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Company may change any Paying Agent or Registrar without notice to any Holder. The Company or any of its Subsidiaries may act in any such capacity.


(4) INDENTURE AND SECURITY DOCUMENTS. The Company issued the Notes under an Indenture dated as of August 5, 2021, as supplemented by a first supplement indenture dated November 22, 2021 and a second supplemental indenture dated as of January 13, 2023 (the “Indenture”) among the Company, the Guarantor and the Trustee. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are secured obligations of the Company. The Notes are secured by a pledge of Collateral (as defined in the Indenture) pursuant to the Security Documents referred to in the Indenture. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

At any time or from time to time prior to October 15, 2029 (three months prior to the maturity of the 2030 Notes) (the “2030 Call Date”), the Company may, at its option, redeem all or a part of the 2030 Notes at a redemption price equal to the 2030 Make-Whole Price plus accrued and unpaid interest on such 2030 Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

2030 Make-Whole Price” with respect to any 2030 Notes to be redeemed, means an amount equal to the greater of:

(1) 100% of the principal amount of such 2030 Notes, without any premium, penalty or charge; and

(2) an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2030 Call Date (assuming the principal amount is scheduled to be paid on the 2030 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate (as defined below) plus 50 basis points.

At any time on or after the 2030 Call Date, the Company may, at its option, redeem all or a part of the 2030 Notes, at a redemption price equal to 100% of the principal amount of the 2030 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).


Treasury Rate” means, as of any redemption date, the yield to maturity as of the earlier of (a) such redemption date or (b) the date on which obligations under the indenture are defeased or satisfied and discharged, of United States Treasury securities with a constant maturity (as compiled and published in the most recent Selected Interest Rates (Daily) H.15 which has become publicly available at least two Business Days (but not more than five Business Days) prior to such date (or, if such release is not so published or available, any publicly available source of similar market data selected by the Company in good faith)) most nearly equal to the period from such date to the 2030 Call Date on which the principal of the 2030 Notes being redeemed will be paid in full; provided, however, that if the period from such date to the 2030 Call Date is not equal to the constant maturity of a United States Treasury security for which a weekly average yield is given, the Treasury Rate shall be obtained by linear interpolation (calculated to the nearest one-twelfth of a year) from the weekly average yields of United States Treasury securities for which such yields are given, except that if the period from such date to the 2030 Call Date is less than one year, the weekly average yield on actually traded United States Treasury securities adjusted to a constant maturity of one year shall be used.

The notice of redemption with respect to the foregoing redemption need not set forth the 2030 Make-Whole Price, but only the manner of calculation thereof. The Company will determine the redemption price (including any 2030 Make-Whole Price) and will notify the Trustee of the redemption price (including any 2030 Make-Whole Price) with respect to any redemption promptly, and the Trustee shall not be responsible for such calculation or determination.

(6) MANDATORY REDEMPTION.

The Company is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control, the Company will make an offer (a “Change of Control Offer”) of payment (a “Change of Control Payment”) to each Holder to repurchase all or any part (equal to $2,000 and integral multiples of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash equal to not less than 101% of the aggregate principal amount of Notes repurchased plus accrued and unpaid interest if any, to the date of repurchase (the “Change of Control Payment Date,” which date will be no earlier than the date of the corresponding Change of Control). No later than 30 days following any Change of Control, the Company will deliver a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Company will be required to make an Asset Sale Offer, Excess Loss Proceeds Offer, PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer to the extent provided in Sections 4.12, 4.19, 4.20 and 4.21, respectively, of the Indenture.

(8) NOTICE OF REDEMPTION. Notice of redemption will be mailed at least 10 days but not more than 60 days before the redemption date to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes or a satisfaction or discharge of the Indenture. Notes in denominations larger than $2,000 may be redeemed in part but only in whole multiples of $1,000 in excess thereof, unless all of the Notes held by a Holder are to be redeemed.


(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form without coupons in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Company may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Company need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Company need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the corresponding Interest Payment Date.

(10) PERSONS DEEMED OWNERS. The registered Holder of a Note may be treated as its owner for all purposes.

(11) TRUSTEE DEALINGS WITH COMPANY. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Company or its Affiliates, and may otherwise deal with the Company or its Affiliates, as if it were not the Trustee.

(12) NO RECOURSE AGAINST OTHERS. No past, present or future director, manager, officer, employee, incorporator, member, partner, Affiliate or stockholder of the Company or any Guarantor (in each case other than the Company and the Guarantors) or the Sponsor, as such, will have any liability for any obligations of the Company or the Guarantors under the Notes, the Indenture, the Note Guarantees, the Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(13) AUTHENTICATION. This Note will not be valid until authenticated by the manual or electronic signature of the Trustee or an authenticating agent.

(14) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(15) CUSIP NUMBERS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Company has caused CUSIP numbers to be printed on the Notes, and the Trustee may use CUSIP numbers in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.


(16) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THIS NOTE AND THE NOTE GUARANTEES.

The Company will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Facsimile No.: [***]

Attention: Treasurer


ASSIGNMENT FORM

 

To assign this Note, fill in the form below:

(I) or (we) assign and transfer this Note  to:                                             
       (Insert assignee’s legal name)

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

(Print or type assignee’s name, address and zip code)

and irrevocably                                                appoint to transfer this Note on the books of the Company. The agent may substitute another to act for him.

Date:       

Your Signature:                     

(Sign exactly as your name appears on the face of this Note)

Signature Guarantee*:        

 

* Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, check the appropriate box below:

 

☐ Section 4.12

  

☐ Section 4.17

  

☐ Section 4.19

  

☐ Section 4.20

☐ Section 4.21

        

If you want to elect to have only part of the Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, state the amount you elect to have purchased:

$      

Date:       

Your Signature:                    

(Sign exactly as your name appears on the face of this Note)

Tax Identification No:                 

Signature Guarantee*:        

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).


SCHEDULE OF EXCHANGES OF INTERESTS IN THE GLOBAL NOTE

The following exchanges of a part of this Global Note for an interest in another Global Note or for a Definitive Note, or exchanges of a part of another Global Note or Definitive Note for an interest in this Global Note, have been made:

 

Date of

Exchange

 

Amount of

decrease in

Principal

Amount [at

maturity] of

this Global

Note

 

Amount of

increase in

Principal

Amount [at

maturity] of

this

Global Note

  

Principal

Amount [at

maturity] of

this Global

Note following

such decrease

(or increase)

  

Signature of

authorized

officer of

Trustee or

Custodian


EXHIBIT A-2

[Face of Regulation S Temporary Global Note]

CUSIP: U9220M AD5

ISIN: USU9220MAD57

6.250% Senior Secured Notes due 2030

 

No.    

   $      

VENTURE GLOBAL CALCASIEU PASS, LLC

promises to pay to       or registered assigns, the principal sum of                        DOLLARS on January 15, 2030.

Interest Payment Dates: January 15 and July 15, commencing July 15, 2023

Record Dates: January 1 and July 1


Dated: January 13, 2023

 

VENTURE GLOBAL CALCASIEU PASS, LLC
By:  

 

Name:  
Title:  

 

This is one of the Notes referred to in the within-mentioned Indenture:

THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A.,

as Trustee

By:  

 

  Authorized Signatory


[Back of Regulation S Temporary Global Note]

6.250% Senior Secured Notes due 2030

THE RIGHTS ATTACHING TO THIS REGULATION S TEMPORARY GLOBAL NOTE, AND THE CONDITIONS AND PROCEDURES GOVERNING ITS EXCHANGE FOR CERTIFICATED NOTES, ARE AS SPECIFIED IN THE INDENTURE (AS DEFINED HEREIN). NEITHER THE HOLDER NOR THE BENEFICIAL OWNERS OF THIS REGULATION S TEMPORARY GLOBAL NOTE SHALL BE ENTITLED TO RECEIVE PAYMENT OF INTEREST HEREON.

THIS GLOBAL NOTE IS HELD BY THE DEPOSITARY (AS DEFINED IN THE INDENTURE GOVERNING THIS NOTE) OR ITS NOMINEE IN CUSTODY FOR THE BENEFIT OF THE BENEFICIAL OWNERS HEREOF, AND IS NOT TRANSFERABLE TO ANY PERSON UNDER ANY CIRCUMSTANCES EXCEPT THAT (1) THE TRUSTEE MAY MAKE SUCH NOTATIONS HEREON AS MAY BE REQUIRED PURSUANT TO SECTION 2.06 OF THE INDENTURE, (2) THIS GLOBAL NOTE MAY BE EXCHANGED IN WHOLE BUT NOT IN PART PURSUANT TO SECTION 2.06(a) OF THE INDENTURE, (3) THIS GLOBAL NOTE MAY BE DELIVERED TO THE TRUSTEE FOR CANCELLATION PURSUANT TO SECTION 2.11 OF THE INDENTURE AND (4) THIS GLOBAL NOTE MAY BE TRANSFERRED TO A SUCCESSOR DEPOSITARY WITH THE PRIOR WRITTEN CONSENT OF THE COMPANY.

UNLESS AND UNTIL IT IS EXCHANGED IN WHOLE OR IN PART FOR NOTES IN DEFINITIVE FORM, THIS NOTE MAY NOT BE TRANSFERRED EXCEPT AS A WHOLE BY THE DEPOSITARY TO A NOMINEE OF THE DEPOSITARY OR BY A NOMINEE OF THE DEPOSITARY TO THE DEPOSITARY OR ANOTHER NOMINEE OF THE DEPOSITARY OR BY THE DEPOSITARY OR ANY SUCH NOMINEE TO A SUCCESSOR DEPOSITARY OR A NOMINEE OF SUCH SUCCESSOR DEPOSITARY. UNLESS THIS CERTIFICATE IS PRESENTED BY AN AUTHORIZED REPRESENTATIVE OF THE DEPOSITORY TRUST COMPANY (55 WATER STREET, NEW YORK, NEW YORK) (“DTC”), TO THE COMPANY OR ITS AGENT FOR REGISTRATION OF TRANSFER, EXCHANGE OR PAYMENT, AND ANY CERTIFICATE ISSUED IS REGISTERED IN THE NAME OF CEDE & CO. OR SUCH OTHER NAME AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC (AND ANY PAYMENT IS MADE TO CEDE & CO. OR SUCH OTHER ENTITY AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC), ANY TRANSFER, PLEDGE OR OTHER USE HEREOF FOR VALUE OR OTHERWISE BY OR TO ANY PERSON IS WRONGFUL INASMUCH AS THE REGISTERED OWNER HEREOF, CEDE & CO., HAS AN INTEREST HEREIN.

THIS NOTE HAS NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), AND MAY NOT BE OFFERED, SOLD, PLEDGED OR OTHERWISE TRANSFERRED EXCEPT IN ACCORDANCE WITH THE FOLLOWING SENTENCE. BY ITS ACQUISITION HEREOF OR OF A BENEFICIAL INTEREST HEREIN, THE ACQUIRER AGREES FOR THE BENEFIT OF VENTURE GLOBAL CALCASIEU PASS, LLC THAT IT WILL NOT OFFER, SELL, PLEDGE OR OTHERWISE TRANSFER THIS NOTE OR ANY BENEFICIAL INTEREST HEREIN, EXCEPT IN ACCORDANCE WITH THE SECURITIES ACT AND ANY APPLICABLE SECURITIES LAWS OF ANY


STATE OF THE UNITED STATES AND ONLY (A) TO VENTURE GLOBAL CALCASIEU PASS, LLC, (B) PURSUANT TO A REGISTRATION STATEMENT WHICH HAS BECOME EFFECTIVE UNDER THE SECURITIES ACT, (C) TO A QUALIFIED INSTITUTIONAL BUYER IN COMPLIANCE WITH RULE 144A UNDER THE SECURITIES ACT, (D) IN AN OFFSHORE TRANSACTION IN COMPLIANCE WITH RULE 904 OF REGULATION S UNDER THE SECURITIES ACT, (E) TO AN INSTITUTIONAL “ ACCREDITED INVESTOR” WITHIN THE MEANING OF RULE 501(a)(1), (2), (3) OR (7) UNDER THE SECURITIES ACT THAT IS NOT A QUALIFIED INSTITUTIONAL BUYER AND THAT IS PURCHASING FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF ANOTHER INSTITUTIONAL ACCREDITED INVESTOR, IN EACH CASE IN A MINIMUM PRINCIPAL AMOUNT OF THE SECURITIES OF $250,000, FOR INVESTMENT PURPOSES AND NOT WITH A VIEW TO OR FOR OFFER OR SALE IN CONNECTION WITH ANY DISTRIBUTION IN VIOLATION OF THE SECURITIES ACT OR (F) PURSUANT TO AN EXEMPTION FROM REGISTRATION PROVIDED BY RULE 144 UNDER THE SECURITIES ACT OR ANY OTHER AVAILABLE EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT. PRIOR TO THE REGISTRATION OF ANY TRANSFER IN ACCORDANCE WITH CLAUSES (C), (D) OR (E) ABOVE, A DULY COMPLETED AND SIGNED CERTIFICATE (THE FORM OF WHICH MAY BE OBTAINED FROM THE TRUSTEE) MUST BE DELIVERED TO THE TRUSTEE. PRIOR TO THE REGISTRATION OF ANY TRANSFER IN ACCORDANCE WITH (F) ABOVE, VENTURE GLOBAL CALCASIEU PASS, LLC RESERVES THE RIGHT TO REQUIRE THE DELIVERY OF SUCH LEGAL OPINIONS, CERTIFICATIONS OR OTHER EVIDENCE AS MAY REASONABLY BE REQUIRED IN ORDER TO DETERMINE THAT THE PROPOSED TRANSFER IS BEING MADE IN COMPLIANCE WITH THE SECURITIES ACT AND APPLICABLE STATE SECURITIES LAWS. NO REPRESENTATION IS MADE AS TO THE AVAILABILITY OF ANY RULE 144 EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT.

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global Calcasieu Pass, LLC, a Delaware limited liability company (the “Company”), promises to pay interest on the principal amount of this Note at 6.250% per annum from January 13, 2023 until maturity. The Company will pay interest semi-annually in arrears on January 15 and July 15 of each year, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from the date of issuance; provided that if there is no existing Unmatured Event of Default or Event of Default in the payment of interest, and if this Note is authenticated between a record date referred to on the face hereof and the next succeeding Interest Payment Date, interest shall accrue from such next succeeding Interest Payment Date; provided further that the first Interest Payment Date shall be July 15, 2023. The Company will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue principal and premium, if any, from time to time on demand at a rate that is 0.50% per annum in excess of the rate then in effect to the extent lawful; it will pay interest (including post-petition interest in any proceeding under any Bankruptcy Law) on overdue installments of interest (without regard to any applicable grace periods) from time to time on demand at the rate equal to 0.50% per annum in excess of the then applicable interest rate on the Notes to the extent lawful. Interest will be computed on the basis of a 360-day year of twelve 30-day months.


Until this Regulation S Temporary Global Note is exchanged for one or more Regulation S Permanent Global Notes, the Holder hereof shall not be entitled to receive payments of interest hereon; until so exchanged in full, this Regulation S Temporary Global Note shall in all other respects be entitled to the same benefits as other Notes under the Indenture.

(2) METHOD OF PAYMENT. The Company will pay interest on the Notes (except defaulted interest) to the Persons who are registered Holders of Notes at the close of business on January 1 or July 1 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium and interest at the office or agency of the Paying Agent or Registrar maintained for such purpose within or without the City and State of New York, or, at the option of the Company, payment of interest may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that payment by wire transfer of immediately available funds will be required with respect to principal of and interest, premium on, all Global Notes and all other Notes the Holders of which will have provided wire transfer instructions to the Company or the Paying Agent. Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Company may change any Paying Agent or Registrar without notice to any Holder. The Company or any of its Subsidiaries may act in any such capacity.

(4) INDENTURE AND SECURITY DOCUMENTS. The Company issued the Notes under an Indenture dated as of August 5, 2021, as supplemented by a first supplement indenture dated November 22, 2021 and a second supplemental indenture dated as of January 13, 2023 (the “Indenture”) among the Company, the Guarantor and the Trustee. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are secured obligations of the Company. The Notes are secured by a pledge of Collateral (as defined in the Indenture) pursuant to the Security Documents referred to in the Indenture. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

At any time or from time to time prior to October 15, 2029 (three months prior to the maturity of the 2030 Notes) (the “2030 Call Date”), the Company may, at its option, redeem all or a part of the 2030 Notes at a redemption price equal to the 2030 Make-Whole Price plus accrued and unpaid interest on such Notes, if any, up to but excluding the redemption date (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).


2030 Make-Whole Price” with respect to any 2030 Notes to be redeemed, means an amount equal to the greater of:

(1) 100% of the principal amount of such 2030 Notes, without any premium, penalty or charge; and

(2) an amount equal to the sum of the present values of the remaining scheduled payments of principal and interest from the redemption date to the 2030 Call Date (assuming the principal amount is scheduled to be paid on the 2030 Call Date and not including any portion of such payments of interest accrued and paid on the redemption date) discounted back to the redemption date on a semi-annual basis (assuming a 360-day year consisting of twelve 30-day months) at the Treasury Rate (as defined below) plus 50 basis points.

At any time on or after the 2030 Call Date, the Company may, at its option, redeem all or a part of the 2030 Notes, at a redemption price equal to 100% of the principal amount of the 2030 Notes to be redeemed, plus accrued and unpaid interest up to but excluding the redemption date, without any premium, penalty or charge (subject to the right of Holders of record on the relevant record date to receive interest due on an interest payment date that is on or prior to the redemption date, without duplication).

Treasury Rate” means, as of any redemption date, the yield to maturity as of the earlier of (a) such redemption date or (b) the date on which obligations under the indenture are defeased or satisfied and discharged, of United States Treasury securities with a constant maturity (as compiled and published in the most recent Selected Interest Rates (Daily) H.15 which has become publicly available at least two Business Days (but not more than five Business Days) prior to such date (or, if such release is not so published or available, any publicly available source of similar market data selected by the Company in good faith)) most nearly equal to the period from such date to the 2030 Call Date on which the principal of the 2030 Notes being redeemed will be paid in full; provided, however, that if the period from such date to the 2030 Call Date is not equal to the constant maturity of a United States Treasury security for which a weekly average yield is given, the Treasury Rate shall be obtained by linear interpolation (calculated to the nearest one-twelfth of a year) from the weekly average yields of United States Treasury securities for which such yields are given, except that if the period from such date to the 2030 Call Date is less than one year, the weekly average yield on actually traded United States Treasury securities adjusted to a constant maturity of one year shall be used.

The notice of redemption with respect to the foregoing redemption need not set forth the 2030 Make-Whole Price, but only the manner of calculation thereof. The Company will determine the redemption price (including any 2030 Make-Whole Price) and will notify the Trustee of the redemption price (including any 2030 Make-Whole Price) with respect to any redemption promptly, and the Trustee shall not be responsible for such calculation or determination.


(6) MANDATORY REDEMPTION.

The Company is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control, the Company will make an offer (a “Change of Control Offer”) of payment (a “Change of Control Payment”) to each Holder to repurchase all or any part (equal to $2,000 and integral multiples of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash equal to not less than 101% of the aggregate principal amount of Notes repurchased plus accrued and unpaid interest if any, to the date of repurchase (the “Change of Control Payment Date,” which date will be no earlier than the date of the corresponding Change of Control). No later than 30 days following any Change of Control, the Company will deliver a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Company will be required to make an Asset Sale Offer, Excess Loss Proceeds Offer, PLD Excess Proceeds Offer or the LNG SPA Mandatory Offer to the extent provided in Sections 4.12, 4.19, 4.20 and 4.21, respectively, of the Indenture.

(8) NOTICE OF REDEMPTION. Notice of redemption will be mailed at least 10 days but not more than 60 days before the redemption date to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes or a satisfaction or discharge of the Indenture. Notes in denominations larger than $2,000 may be redeemed in part but only in whole multiples of $1,000 in excess thereof, unless all of the Notes held by a Holder are to be redeemed.

(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form without coupons in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Company may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Company need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Company need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the corresponding Interest Payment Date.

This Regulation S Temporary Global Note is exchangeable in whole or in part for one or more Global Notes only (i) on or after the termination of the 40-day distribution compliance period (as defined in Regulation S) and (ii) upon presentation of certificates (accompanied by an Opinion of Counsel, if applicable) required by Article 2 of the Indenture. Upon exchange of this Regulation S Temporary Global Note for one or more Global Notes, the Trustee shall cancel this Regulation S Temporary Global Note.


(10) PERSONS DEEMED OWNERS. The registered Holder of a Note may be treated as its owner for all purposes.

(11) TRUSTEE DEALINGS WITH COMPANY. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Company or its Affiliates, and may otherwise deal with the Company or its Affiliates, as if it were not the Trustee.

(12) NO RECOURSE AGAINST OTHERS. No past, present or future director, manager, officer, employee, incorporator, member, partner, Affiliate or stockholder of the Company or any Guarantor (in each case other than the Company and the Guarantors) or the Sponsor, as such, will have any liability for any obligations of the Company or the Guarantors under the Notes, the Indenture, the Note Guarantees, the Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(13) AUTHENTICATION. This Note will not be valid until authenticated by the manual or electronic signature of the Trustee or an authenticating agent.

(14) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(15) CUSIP NUMBERS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Company has caused CUSIP numbers to be printed on the Notes, and the Trustee may use CUSIP numbers in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

(16) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THIS NOTE AND THE NOTE GUARANTEES.

The Company will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global Calcasieu Pass, LLC

c/o Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Facsimile No.: [***]

Attention: Treasurer


ASSIGNMENT FORM

 

To assign this Note, fill in the form below:

(I) or (we) assign and transfer this Note  to:                                             
       (Insert assignee’s legal name)

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

(Print or type assignee’s name, address and zip code)

and irrevocably                                                appoint to transfer this Note on the books of the Company. The agent may substitute another to act for him.

Date:       

Your Signature:                     

(Sign exactly as your name appears on the face of this Note)

Signature Guarantee*:        

 

 

* Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, check the appropriate box below:

 

☐ Section 4.12

  

☐ Section 4.17

  

☐ Section 4.19

  

☐ Section 4.20

☐ Section 4.21

        

If you want to elect to have only part of the Note purchased by the Company pursuant to Section 4.12, Section 4.17, Section 4.19, Section 4.20, Section 4.21 of the Indenture, state the amount you elect to have purchased:

$      

Date:       

Your Signature:                    

(Sign exactly as your name appears on the face of this Note)

Tax Identification No:                 

Signature Guarantee*:        

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).


SCHEDULE OF EXCHANGES OF INTERESTS IN THE REGULATIONS

TEMPORARY GLOBAL NOTE

The following exchanges of a part of this Regulation S Temporary Global Note for an interest in another Global Note, or exchanges of a part of another other Restricted Global Note for an interest in this Regulation S Temporary Global Note, have been made:

 

Date of

Exchange

 

Amount of

decrease in

Principal

Amount [at

maturity] of

this Global

   Note   

 

Amount of

increase in

Principal

Amount [at

maturity] of

this Global

   Note   

 

Principal Amount

[at maturity] of this

Global Note

following such

decrease (or

   increase)   

 

Signature of

authorized officer of

 Trustee or Custodian 

Exhibit 10.86

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

 

 

AMENDED AND RESTATED CREDIT FACILITY AGREEMENT

 

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC,

as Borrower,

 

 

VENTURE GLOBAL GATOR EXPRESS, LLC,

as Guarantor,

 

 

THE LENDERS PARTY HERETO FROM TIME TO TIME,

as Lenders,

THE ISSUING BANKS HERETO FROM TIME TO TIME,

as Issuing Banks,

and

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

and

solely for purposes of Section 3.06,

ROYAL BANK OF CANADA,

as Collateral Agent

 

 

Dated as of March 13, 2023


TABLE OF CONTENTS

 

         Page  

ARTICLE I DEFINITIONS AND INTERPRETATION

     2  

Section 1.01

  Defined Terms      2  

Section 1.02

  Principles of Interpretation      2  

Section 1.03

  UCC Terms      2  

Section 1.04

  Accounting and Financial Determinations      2  

Section 1.05

  Designations      3  

Section 1.06

  Rates      3  

Section 1.07

  Divisions      3  

ARTICLE II COMMITMENTS AND ADVANCES

     3  

Section 2.01

  Term Loans      3  

Section 2.02

  Term Loan Availability      5  

Section 2.03

  Working Capital Loans      6  

Section 2.04

  Working Capital Loan Availability      6  

Section 2.05

  Procedures for Requesting Advances      7  

Section 2.06

  Funding      9  

Section 2.07

  Termination or Reduction of Commitments      11  

Section 2.08

  Incremental Commitments      13  

Section 2.09

  Use of Proceeds      15  

ARTICLE III LETTERS OF CREDIT

     16  

Section 3.01

  Letters of Credit      16  

Section 3.02

  Reimbursement to Issuing Banks      19  

Section 3.03

  Obligations Absolute      21  

Section 3.04

  Liability of the Issuing Banks and the Working Capital Lenders      22  

Section 3.05

  Resignation as an Issuing Bank      22  

Section 3.06

  Non-Fronted Letters of Credit      23  

Section 3.07

  Reinstatement of Letters of Credit      23  

Section 3.08

  Existing Letters of Credit      24  

ARTICLE IV REPAYMENTS, PREPAYMENTS, INTEREST AND FEES

     24  

Section 4.01

  Repayment of Term Loan Advances      24  

Section 4.02

  Repayment of LC Loans      25  

Section 4.03

  Repayment of Working Capital Advances      25  

Section 4.04

  Interest Payment Dates      25  

Section 4.05

  Interest Rates      26  

Section 4.06

  Conversion Options      27  

Section 4.07

  Post-Maturity Interest Rates; Default Interest Rates      28  

Section 4.08

  Interest Rate Determination      28  

 

i


Section 4.09

  Computation of Interest and Fees      28  

Section 4.10

  Terms of All Prepayments      28  

Section 4.11

  Voluntary Prepayment      29  

Section 4.12

  Mandatory Prepayment      30  

Section 4.13

  Time and Place of Payments      30  

Section 4.14

  Advances and Payments Generally      31  

Section 4.15

  Fees      31  

Section 4.16

  Pro Rata Treatment      33  

Section 4.17

  Sharing of Payments      33  

Section 4.18

  Defaulting Lenders      34  
ARTICLE V SOFR AND TAX PROVISIONS      36  

Section 5.01

  Illegality      36  

Section 5.02

  Inability to Determine Applicable Interest Rate      37  

Section 5.03

  Increased Costs      38  

Section 5.04

  Obligation to Mitigate      38  

Section 5.05

  Funding Losses      39  

Section 5.06

  Taxes      39  

Section 5.07

  Replacement Benchmark Setting      39  
ARTICLE VI REPRESENTATIONS AND WARRANTIES      41  

Section 6.01

  Incorporation of Common Terms Agreement      41  
ARTICLE VII CONDITIONS PRECEDENT      41  

Section 7.01

  Conditions to Initial Closing      41  

Section 7.02

  Conditions to Upsize Closing      41  

Section 7.03

  Conditions to Each Term Loan Advance      42  

Section 7.04

  Conditions to Each Working Capital Advance      42  

Section 7.05

  Conditions to Occurrence of the Project Phase 1 Completion Date      42  

Section 7.06

  Conditions to Occurrence of the Project Phase 2 Completion Date      42  
ARTICLE VIII COVENANTS      43  

Section 8.01

  Covenants      43  
ARTICLE IX DEFAULT AND ENFORCEMENT      43  

Section 9.01

  Events of Default      43  

Section 9.02

  Acceleration Upon Bankruptcy      43  

Section 9.03

  Action Upon Event of Default      43  

Section 9.04

  Cash Collateralization of Letters of Credit      44  

Section 9.05

  Application of Proceeds      45  

 

ii


ARTICLE X THE CREDIT FACILITY AGENT      45  

Section 10.01

  Appointment and Authority      45  

Section 10.02

  Rights as a Facility Lender or Hedging Bank      46  

Section 10.03

  Exculpatory Provisions      46  

Section 10.04

  Reliance by Credit Facility Agent      48  

Section 10.05

  Delegation of Duties      49  

Section 10.06

  Indemnification by the Lenders      49  

Section 10.07

  Resignation or Removal of Credit Facility Agent      50  

Section 10.08

  No Amendment to Duties of Credit Facility Agent Without Consent      51  

Section 10.09

  Non-Reliance on Credit Facility Agent, Lenders and Issuing Banks      51  

Section 10.10

  No Coordinating Lead Arranger or Documentation Bank Duties      52  

Section 10.11

  Copies      52  

Section 10.12

  General Provisions as to Payments      52  

Section 10.13

  Agreement to Comply with Finance Documents      53  

Section 10.14

  Certain ERISA Matters      53  

Section 10.15

  Erroneous Payments      54  
ARTICLE XI MISCELLANEOUS PROVISIONS      57  

Section 11.01

  Decisions; Amendments, Etc.      57  

Section 11.02

  Entire Agreement      61  

Section 11.03

  Applicable Government Rule; Jurisdiction; Etc.      61  

Section 11.04

  Assignments      61  

Section 11.05

  Benefits of Agreement      68  

Section 11.06

  Counterparts; Effectiveness      68  

Section 11.07

  Indemnification by the Obligors      68  

Section 11.08

  Interest Rate Limitation      69  

Section 11.09

  No Waiver; Cumulative Remedies      69  

Section 11.10

  Notices and Other Communications      69  

Section 11.11

  USA Patriot Act Notice      70  

Section 11.12

  Payments Set Aside      70  

Section 11.13

  Right of Set-Off      71  

Section 11.14

  Severability      71  

Section 11.15

  Survival      71  

Section 11.16

  Treatment of Certain Information; Confidentiality      71  

Section 11.17

  Waiver of Consequential Damages, Etc.      72  

Section 11.18

  Waiver of Litigation Payments      72  

Section 11.19

  Reinstatement      72  

Section 11.20

  No Recourse      72  

Section 11.21

  Intercreditor Agreement      72  

Section 11.22

  Termination      73  

 

iii


Section 11.23

  Acknowledgement and Consent to Bail-In of Affected Financial Institutions      73  

Section 11.24

  Acknowledgment Regarding any Supported QFCs      73  

Section 11.25

  Data Protection; Information Exchange      74  

Section 11.26

  Amendment and Restatement      74  

 

SCHEDULES

     

Schedule I

     -     

Lenders, Commitments

Schedule II

     -     

Issuing Bank Limits

Schedule III

     -     

Amortization Schedule

Schedule IV

     -     

Credit Facility Agent Account Details

Schedule V

     -     

Existing Letters of Credit

EXHIBITS

     

Exhibit A

     -     

Definitions

Exhibit B-1

     -     

Form of Term Loan Note

Exhibit B-2

     -     

Form of Working Capital Note

Exhibit C-1

     -     

Form of Letter of Credit – TGP

Exhibit C-2

     -     

Form of Letter of Credit – TETCO

Exhibit C-3

     -     

Form of Letter of Credit – TETCO

Exhibit D

     -     

Form of Interest Period Notice

Exhibit E

     -     

Form of Lender Assignment Agreement

 

iv


AMENDED AND RESTATED CREDIT FACILITY AGREEMENT

This AMENDED AND RESTATED CREDIT FACILITY AGREEMENT, dated as of March 13, 2023 (the “Credit Facility Agreement” or this “Agreement”), is made among:

VENTURE GLOBAL PLAQUEMINES LNG, LLC, a limited liability company organized under the laws of the State of Delaware (the “Borrower”),

VENTURE GLOBAL GATOR EXPRESS, LLC, a limited liability company organized under the laws of the State of Delaware (the “Guarantor”),

NATIXIS, NEW YORK BRANCH, in its capacity as administrative agent for the Lenders and Issuing Banks hereunder (and, together with each other Person that may, from time to time, be appointed as successor Credit Facility Agent in accordance with Section 10.07 (Resignation or Removal of Credit Facility Agent), the “Credit Facility Agent”),

Solely for purposes of Section 3.06 (Non-Fronted Letters of Credit), ROYAL BANK OF CANADA, as the Collateral Agent (the “Collateral Agent”),

Each of the Issuing Banks party hereto from time to time, and

Each of the Lenders party hereto from time to time.

WHEREAS, the Borrower intends to engage in the Development;

WHEREAS, on the Initial Closing Date (i) the Initial Working Capital Lenders and the Initial Issuing Banks established a working capital credit facility in order to provide loans and letters of credit which are to be used by, or otherwise be issued for the account of, the Obligors, as set forth herein and in the other Finance Documents (the “Initial Working Capital Facility”), and (ii) the Initial Term Lenders established a credit facility in order to provide funds which are to be used to partially finance the Development through the payment of Project Costs and otherwise, as set forth herein and in the other Finance Documents;

WHEREAS, the Borrower has requested that (i) (A) the Incremental Working Capital Lenders and the Incremental Issuing Banks provide incremental commitments under the Initial Working Capital Facility in order to provide loans and letters of credit which are to be used by, or otherwise be issued for the account of, the Obligors, as set forth herein and in the other Finance Documents (the Initial Working Capital Facility as increased, the “Working Capital Facility”), and (ii) the Incremental Term Lenders provide incremental commitments under the credit facility in order to provide funds which are to be used to partially finance the Development through the payment of Project Costs and otherwise, as set forth herein and in the other Finance Documents;

WHEREAS, pursuant to that certain Assignment of Intercompany Loan Agreement, dated as of May 25, 2022, by and between the Borrower, the Guarantor, the Sponsor and the Credit Facility Agent, the Sponsor has assigned to the Credit Facility Agent all of its right, title and interest in and to that certain Intercompany Loan Agreement, dated as of July 26, 2021, by and between the Sponsor, as lender, and the Borrower, as Borrower (the “Intercompany Loan Agreement”), and the loans to the Borrower made thereunder in the principal amount of up to $150,000,000; and


WHEREAS, on the Initial Closing Date, the Borrower, the Guarantor, the Credit Facility Agent, Working Capital Lenders, the Issuing Banks, the Term Lenders and, solely for purposes of Section 3.06 (Non-Fronted Letters of Credit), the Collateral Agent, amended and restated the Intercompany Loan Agreement to make such credit facilities available upon and subject to the terms and conditions set forth in the Original Credit Facility Agreement.

NOW THEREFORE, in consideration of the foregoing, and for other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, the parties hereto hereby amend and restate the Original Credit Facility Agreement in its entirety and agree as follows:

ARTICLE I

DEFINITIONS AND INTERPRETATION

Section 1.01 Defined Terms. Unless otherwise defined in Exhibit A, capitalized terms used in this Agreement (including the preamble hereto) shall have the meanings provided in Section 1.3 (Definitions) of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement.

Section 1.02 Principles of Interpretation. Unless otherwise provided herein, this Agreement shall be governed by the principles of interpretation provided in Section 1.2 (Interpretation) of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement, mutatis mutandis.

Section 1.03 UCC Terms. Unless otherwise defined herein or in Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement, terms used herein that are defined in the UCC shall have the respective meanings given to those terms in the UCC.

Section 1.04 Accounting and Financial Determinations. Except as otherwise expressly provided herein, all terms of an accounting or financial nature shall be construed in accordance with GAAP, as in effect from time to time; provided that, if the Borrower notifies the Intercreditor Agent and the Credit Facility Agent that the Borrower requests an amendment to any provision hereof to eliminate the effect of any change occurring after the Upsize Closing Date in GAAP or in the application thereof on the operation of, or calculation of compliance with, such provision so as to preserve the original intent thereof in light of such change in GAAP (or if the Intercreditor Agent and Credit Facility Agent, as the case may be, notifies the Borrower that the Required Lenders request an amendment to any provision hereof for such purpose), regardless of whether any such notice is given before or after such change in GAAP or in the application thereof, then such provision shall be interpreted on the basis of GAAP as in effect and applied immediately before such change shall have become effective until such provision has been amended in accordance herewith.

 

2


Section 1.05 Designations. This Agreement is a Facility Agreement and a Senior Debt Instrument, the Term Lenders, Working Capital Lenders and Issuing Banks in this Agreement are Senior Creditors and the Credit Facility Agent is the Senior Creditor Group Representative of the Term Lenders, the Working Capital Lenders and the Issuing Banks, in each case under the Finance Documents.

Section 1.06 Rates. The Credit Facility Agent does not warrant or accept responsibility for, and shall not have any liability with respect to (a) the continuation of, administration of, submission of, calculation of or any other matter related to the Base Rate, the Term SOFR Reference Rate or Term SOFR, or any component definition thereof or rates referred to in the definition thereof, or any alternative, successor or replacement rate thereto (including any Benchmark Replacement), including whether the composition or characteristics of any such alternative, successor or replacement rate (including any Benchmark Replacement) will be similar to, or produce the same value or economic equivalence of, or have the same volume or liquidity as, the Base Rate, the Term SOFR Reference Rate, Term SOFR or any other Benchmark prior to its discontinuance or unavailability, or (b) the effect, implementation or composition of any Conforming Changes. The Credit Facility Agent and its affiliates or other related entities may engage in transactions that affect the calculation of the Base Rate, the Term SOFR Reference Rate, Term SOFR, any alternative, successor or replacement rate (including any Benchmark Replacement) or any relevant adjustments thereto, in each case, in a manner adverse to the Borrower. The Credit Facility Agent may select information sources or services in its reasonable discretion to ascertain the Base Rate, the Term SOFR Reference Rate, Term SOFR or any other Benchmark, in each case pursuant to the terms of this Agreement, and shall have no liability to the Borrower, any Lender or any other person or entity for damages of any kind, including direct or indirect, special, punitive, incidental or consequential damages, costs, losses or expenses (whether in tort, contract or otherwise and whether at law or in equity), for any error or calculation of any such rate (or component thereof) provided by any such information source or service.

Section 1.07 Divisions. For all purposes under the Finance Documents, in connection with any division or plan of division under Delaware law (or any comparable event under a different jurisdiction’s laws): (a) if any asset, right, obligation or liability of any Person becomes the asset, right, obligation or liability of a different Person, then it shall be deemed to have been transferred from the original Person to the subsequent Person, and (b) if any new Person comes into existence, such new Person shall be deemed to have been organized on the first date of its existence by the holders of its Equity Interests at such time.

 

3


ARTICLE II

COMMITMENTS AND ADVANCES

On the terms, subject to the conditions and relying upon the representations and warranties herein set forth:

Section 2.01 Term Loans. (a) Each Term Lender, severally and not jointly, shall make Term Loans to the Borrower: (i) in an aggregate principal amount not in excess of the Base Term Loan Commitments of such Term Lender, if any, from time to time during the Term Loan Availability Period but not more frequently than as permitted under Section 2.05 (Procedures for Requesting Advances) for use in accordance with Section 2.09(a)(i) (Use of Proceeds); and (ii) in an aggregate principal amount not in excess of the Contingency Reserve Term Loan Commitments of such Term Lender, if any, from time to time during the Term Loan Availability Period but not more frequently than as permitted under Section 2.05 (Procedures for Requesting Advances) for use in accordance with Section 2.09(a)(ii) (Use of Proceeds); provided that, after giving effect to the making of any Term Loans, the aggregate outstanding principal amount of all Term Loans shall not exceed the Aggregate Term Loan Commitments. The aggregate amount of the Base Term Loan Commitments as of the Upsize Closing Date is $[***] and the aggregate amount of the Contingency Reserve Term Loan Commitments as of the Upsize Closing Date is $[***]. On the Project Phase 1 Completion Date, the aggregate amount of the Contingency Reserve Term Loan Commitments shall be reduced ratably across the Term Lenders with Contingency Reserve Term Loan Commitments such that the funds on deposit in the Contingency Reserve Account after given effect to any transfer on the Project Phase 1 Completion Date pursuant to Section 4.5(k)(iii) (Deposits and Withdrawals – Contingency Reserve Account) of the Common Security and Account Agreement and the remaining undrawn amount of the Contingency Reserve Term Loan Commitments are, collectively, equal to the Contingency Reserve Amount (as adjusted on the Project Phase 1 Completion Date) and the Base Term Loan Commitments of Lenders with Base Term Loan Commitments shall be increased ratably dollar- for-dollar and the Credit Facility Agent shall update the Register in accordance with Section 2.06(e) (Funding) to reflect such updates to the Commitments. The entries made by the Credit Facility Agent in the Register or the accounts maintained by any Lender shall be conclusive and binding evidence, absent manifest error, of the existence and amounts of the obligations recorded therein; provided that, the failure of any Lender or the Credit Facility Agent to maintain such Register or accounts or any error therein shall not in any manner affect the obligation of the Borrower to repay the Loans in accordance with the terms of this Agreement.

(b) Each Term Loan Advance shall be in an amount specified in the relevant Disbursement Request.

(c) Except as set forth in clause (d) below, proceeds of the Term Loans shall be deposited into the Construction Account in accordance with Section 4.5(a) (Deposits and Withdrawals – Disbursements of Senior Debt) of the Common Security and Account Agreement. The Obligors shall not request or apply any portion of any Term Loan other than in accordance with this Section 2.01 (Term Loans), Sections 2.02 (Term Loan Availability) and 2.09 (Use of Proceeds) of this Agreement and Sections 2.3 (Loan Disbursement and Letter of Credit Issuance Procedures), 2.4 (Pro Rata Advances), 2.6 (Currency) and 12.1 (Use of Proceeds) of the Common Terms Agreement. Neither the Credit Facility Agent nor the Term Lenders are under any obligation hereunder to inquire into or verify the application of any Term Loan but this does not affect or limit the Obligors’ obligations hereunder or under the Common Terms Agreement.

(d) Notwithstanding Section 2.01(c), proceeds of the Term Loans funded from the Contingency Reserve Term Loan Commitment (excluding any such proceeds used to fund the Construction Account on the Project Phase 2 Completion Date (as specified in Section 14.4(b) (Project Phase 2 Completion Date Waterfall – Final Advance of Term Loans) of the Common Terms Agreement)) shall be paid into the Contingency Reserve Account in accordance with

 

4


Section 4.5(k) (Deposits and Withdrawals – Contingency Reserve Account) of the Common Security and Account Agreement; provided that, such transfer shall occur on the same day that the Credit Facility Agent receives such proceeds from the Term Lenders and subject to the Credit Facility Agent’s actual receipt of such proceeds in accordance with Section 2.06(a) (Funding). For the avoidance of doubt, such Advances shall constitute a Term Loan for all purposes under this Agreement and each other Finance Document and shall be treated as received, and accounted for as a Term Loan, by the Borrower.

(e) Term Loans that are repaid or prepaid may not be reborrowed.

Section 2.02 Term Loan Availability. (a) Subject to the terms and conditions set forth in this Agreement and the Common Terms Agreement, each Term Lender severally, and not jointly or jointly and severally, agrees to advance to the Borrower its pro rata share of such Term Lender’s Term Loan Commitment as the Borrower may request under this Section 2.02 (Term Loan Availability) and the applicable Disbursement Request (each such Advance when made, individually, a “Term Loan” and, collectively, the “Term Loans”), in an aggregate principal amount not to exceed such Term Lender’s Term Loan Commitment, from time to time during the period commencing on the Initial Closing Date and ending on the earliest of (such period, the “Term Loan Availability Period”):

(i) the Phase 2 LNG Facility Date Certain;

(ii) the Project Phase 2 Completion Date;

(iii) the date the Term Loan Commitments are fully utilized or of any cancellation or termination of all of the remaining Term Loan Commitments pursuant to Section 3.8 (Reductions and Cancellations of Facility Debt Commitments) of the Common Terms Agreement; and

(iv) the date the Required Lenders terminate their Commitments upon the occurrence and during the Continuance of a Loan Facility Event of Default.

(b) Subject to Section 7.01 (Conditions to Initial Closing) (which incorporates by reference Section 4.1 (Conditions to Initial Closing Date and Initial Advance) of the Common Terms Agreement), Section 7.02 (Conditions to Upsize Closing) (which incorporates by reference Section 4.2 (Conditions to Upsize Closing Date) of the Common Terms Agreement), Section 7.03 (Conditions to Each Term Loan Advance) (which incorporates by reference Section 4.3 (Conditions to Each Term Loan Advance) of the Common Terms Agreement), Section 2.2 (Sequence of Advances of Senior Debt) of the Common Terms Agreement, Section 2.4 (Pro Rata Advances) of the Common Terms Agreement and the applicable conditions of Article 4 (Conditions Precedent) of the Common Terms Agreement and Section 2.02(a) (Term Loan Availability) of this Agreement, the Borrower shall be entitled to draw down all or a portion of the unused Term Loan Commitments before or on the final date of the Term Loan Availability Period for the purposes set forth in Section 12.1 (Use of Proceeds) of the Common Terms Agreement and Section 2.09 (Use of Proceeds) of this Agreement.

 

5


Section 2.03 Working Capital Loans. (a) Each Working Capital Lender, severally and not jointly, shall make Working Capital Loans to the Borrower in an aggregate principal amount not in excess of its Working Capital Commitment from time to time during the Working Capital Loan Availability Period; provided that, after giving effect to the making of any Working Capital Loans, (i) the aggregate Working Capital Commitment Exposure for all Working Capital Lenders shall not exceed the Aggregate Working Capital Commitments and (ii) no Working Capital Lender shall be required to make any Working Capital Loan if such Working Capital Lender’s Working Capital Commitment Exposure would exceed its Working Capital Commitment.

(b) Each Working Capital Advance shall be in an amount specified in the relevant Disbursement Request.

(c) Proceeds of the Working Capital Loans shall be deposited or applied in accordance with Section 4.5(a) (Deposits and Withdrawals – Disbursements of Senior Debt) of the Common Security and Account Agreement. The Obligors shall not request or apply any portion of any Working Capital Loan other than in accordance with this Section 2.03 (Working Capital Loans), Sections 2.04 (Working Capital Loan Availability) and 2.09 (Use of Proceeds) of this Agreement and Sections 2.3 (Loan Disbursement and Letter of Credit Issuance Procedures) and 2.6 (Currency) of the Common Terms Agreement. Neither the Credit Facility Agent nor the Working Capital Lenders are under any obligation hereunder to inquire into or verify the application of any Working Capital Loan but this does not affect or limit any Obligor’s obligations hereunder or under the Common Terms Agreement.

(d) Working Capital Loans repaid or prepaid, except in accordance with Sections 4.12(b)(ii), (iii) and (iv) (Mandatory Prepayment), may be re-borrowed at any time and from time to time up to but excluding the Working Capital Loan Termination Date. Each Working Capital Lender’s Working Capital Commitment shall expire on the Working Capital Loan Termination Date and all other amounts owed hereunder with respect to Working Capital Loans and the Working Capital Commitments shall be paid in full no later than such date.

Section 2.04 Working Capital Loan Availability. (a) Subject to the terms and conditions set forth in this Agreement and the Common Terms Agreement, each Working Capital Lender severally, and not jointly or jointly and severally, agrees to make Advances to the Borrower in the amount of its Commitment Percentage of the amount the Borrower may request, in accordance with this Section 2.04 (Working Capital Loan Availability) and the applicable Disbursement Request (each such Advance, when made, individually, a “Working Capital Loan” and, collectively, the “Working Capital Loans”), in an aggregate principal amount not to exceed such Working Capital Lender’s unused Working Capital Commitment such that its Working Capital Commitment Exposure does not exceed its Working Capital Commitment after giving effect to such Working Capital Loan, from time to time during the period commencing on the Initial Closing Date and, in each case, ending on the earliest to occur of the following dates (the “Working Capital Loan Termination Date”) (such period, the “Working Capital Loan Availability Period”):

(i) the Final Maturity Date;

 

6


(ii) the date of any cancellation or termination of all of the remaining Working Capital Commitments pursuant to Section 2.07 (Termination or Reduction of Commitments); and

(iii) the date the Working Capital Lenders terminate their Working Capital Commitments upon the occurrence and during the Continuance of a Working Capital Facility Event of Default.

(b) Subject to the conditions of Section 2.03 (Working Capital Loans), Section 7.01 (Conditions to Initial Closing) (which incorporates by reference Section 4.1 (Conditions to Initial Closing Date and Initial Advance) of the Common Terms Agreement), Section 7.02 (Conditions to Upsize Closing) (which incorporates by reference Section 4.2 (Conditions to Upsize Closing Date) of the Common Terms Agreement) and Section 7.04 (Conditions to Each Working Capital Advance) of this Agreement (which incorporates by reference Section 4.4 (Conditions to Each Advance under the Working Capital Facility) of the Common Terms Agreement), and this Section 2.04 (Working Capital Loan Availability), the Borrower shall be entitled to draw all or a portion of the unused Working Capital Commitments before or on the final date of the Working Capital Loan Availability Period for the purposes set forth in Section 12.1 (Use of Proceeds) of the Common Terms Agreement and Section 2.09(b) (Use of Proceeds).

Section 2.05 Procedures for Requesting Advances.

(a) From time to time, but no more frequently than twice per calendar month (except as required for the payment of interest or Commitment Fees during the Term Loan Availability Period, and for any draw of remaining Term Loan Commitments on the last day of the Term Loan Availability Period), subject to the limitations set forth in Sections 2.01 (Term Loans), and 2.02 (Term Loan Availability) above and Sections 2.2 (Sequence of Advances of Senior Debt) and 2.4 (Pro Rata Advances) of the Common Terms Agreement, the Borrower may request a Term Loan Advance by delivering to the Credit Facility Agent a properly completed Disbursement Request in accordance with Section 2.3 (Loan Disbursement and Letter of Credit Procedures) of the Common Terms Agreement and this Section 2.05 (Procedures for Requesting Advances).

(b) The aggregate amount of any proposed Term Loan Advance under this Agreement must be an amount that is no more than the available Term Loan Commitments and not less than $10,000,000 and an integral multiple of $1,000,000 (unless the available Term Loan Commitments are less than $10,000,000). Such Advances shall be made pro rata with respect to other Facility Agreements in accordance with the committed principal amounts under the Term Loan Commitment subject to and in accordance with Section 2.4 (Pro Rata Advances) of the Common Terms Agreement.

(c) From time to time, subject to the limitations set forth in Section 2.03 (Working Capital Loans) and Section 2.04 (Working Capital Loan Availability) above, the Borrower may request a Working Capital Advance by delivering to the Credit Facility Agent a properly completed Disbursement Request in accordance with this Section 2.05 (Procedures for Requesting Advances) and Section 2.3 (Loan Disbursement and Letter of Credit Procedures) of the Common Terms Agreement. Working Capital Advances under this Agreement may be made concurrently with but shall not be required to be made pro rata with borrowings under any other Facility Agreements. For the avoidance of doubt, Working Capital Advances shall be required to be borrowed pro rata based on each Working Capital Lender’s Commitment Percentage.

 

7


(d) The amount of any proposed Working Capital Advance under this Agreement must be an amount that is no more than the unused Aggregate Working Capital Commitments and not less than $5,000,000 and an integral multiple of $1,000,000 (unless the unused Aggregate Working Capital Commitments are less than $5,000,000).

(e) The Credit Facility Agent shall promptly advise each Lender that has a Commitment that is to fund any portion of the Term Loan Advance or Working Capital Advance, as applicable, of any Disbursement Request delivered pursuant to this Section 2.05 (Procedures for Requesting Advances), together with each such Lender’s Commitment Percentage of the requested Advance.

(f) Any Disbursement Request delivered pursuant to clause (a) or (c) above shall be delivered by the Borrower to the Credit Facility Agent by 1:00 p.m. on or before the third (3rd) U.S. Government Securities Business Day prior to the requested Advance Date for the Advance of any SOFR Loans and 1:00 p.m. on or before the Business Day prior to the requested Advance Date for the Advance of any Base Rate Loans; provided that, the notice periods set forth in this clause (f) shall not apply with respect to the Disbursement Request for the Initial Advance, which Disbursement Request may be delivered no later than 11:00 a.m. on the Business Day before the requested Advance Date.

(g) Each Disbursement Request delivered pursuant to this Section 2.05 (Procedures for Requesting Advances) shall be substantially in the form of Schedule B-1 to the Common Terms Agreement (Disbursement Request Form (Term Loans)) or Schedule B-2 to the Common Terms Agreement (Disbursement Request Form (Working Capital Loans)). Each such Disbursement Request shall be irrevocable and shall refer to this Agreement and specify:

(i) whether the requested Advance is of Working Capital Loans or Term Loans and, to the extent the requested Advance would constitute Term Loans, whether the requested Advance is to be funded from the Base Term Loan Commitment and/or the Contingency Reserve Term Loan Commitment;

(ii) the requested Advance Date (which shall be a Business Day);

(iii) the amount of such requested Advance (including, where applicable, the amount to be funded from the Base Term Loan Commitment and/or the Contingency Reserve Term Loan Commitment);

(iv) whether the requested Advance is of SOFR Loans or Base Rate Loans;

(v) in the case of a requested Advance of SOFR Loans, the Borrower’s election with respect to the duration of the initial Interest Period applicable to such SOFR Loans, which Interest Period shall be one (1), three (3) or six (6) months in length (or, if available to all applicable Lenders, such other periods as may be agreed by the Credit Facility Agent (including with respect to the Applicable Margin agreed to by all the Lenders with respect to any such Interest Period));

 

8


(vi) if the requested Advance is (A) of a Term Loan, that each of the conditions precedent to such Term Loan Advance has been satisfied or waived in accordance with Section 7.01 (Conditions to Initial Closing), Section 7.02 (Conditions to Upsize Closing) or Section 7.03 (Conditions to Each Term Loan Advance), as applicable, or (B) of a Working Capital Loan, that each of the conditions precedent to such Working Capital Advance has been satisfied or waived in accordance with Section 7.01 (Conditions to Initial Closing), Section 7.02 (Conditions to Upsize Closing) or Section 7.04 (Conditions to Each Working Capital Advance), as applicable;

(vii) if such Disbursement Request is being made pursuant to Section 2.09(a) or Section 2.09(b) (Use of Proceeds); and

(viii) the wire information of the account to which the proceeds of such Advance are to be deposited.

The currency specified in a Disbursement Request must be US Dollars.

(h) If no election as to whether the requested Advance is of SOFR Loans or Base Rate Loans, then the requested Advance shall be of SOFR Loans; provided that, if the applicable Disbursement Request is delivered to the Credit Facility Agent later than 1:00 p.m. on the third (3rd) U.S. Government Securities Business Day prior to the proposed Advance Date, the requested Advance shall be of Base Rate Loans. If no initial Interest Period is specified with respect to any requested SOFR Loans, then the requested Advance shall be made as a SOFR Loan with an initial Interest Period of one (1) month.

Section 2.06 Funding. (a) Subject to clause (c) below, on the proposed Advance Date of each Advance, each Lender shall make a Term Loan or a Working Capital Loan, as applicable, in the amount of its Commitment Percentage of such Advance by wire transfer of immediately available funds to the Credit Facility Agent, not later than 1:00 p.m. and the Credit Facility Agent shall transfer and deposit the amounts (i) constituting proceeds of Term Loans so received as set forth in Section 2.01(c) or (d) (Term Loans), as applicable, for application in accordance with Section 4.5(a) (Deposits and Withdrawals Disbursements of Senior Debt), Section 4.5(d) (Deposits and Withdrawals Construction Account) and Section 4.5(k) (Deposits and Withdrawals – Contingency Reserve Account) of the Common Security and Account Agreement, as applicable, and (ii) constituting proceeds of Working Capital Loans so received as set forth in Section 2.03(c) (Working Capital Loans); provided that, if an Advance does not occur on the proposed Advance Date because any condition precedent to such requested Advance herein specified has not been met, the Credit Facility Agent shall return the amounts so received to each applicable Lender without interest as soon as possible. It is acknowledged and agreed by the parties hereto that, as of the Upsize Closing Date, the outstanding Term Loans are not pro rata based on the Commitment Percentage of each Lender. Notwithstanding anything to the contrary contained herein or in any other Finance Document (including Section 2.4 (Pro Rata Advances) of the Common Terms Agreement, but subject to the satisfaction of the applicable conditions of Article 4 (Conditions Precedent) of the Common Terms Agreement and Section 2.02(a) (Term Loan

 

9


Availability) of this Agreement), on the first Advance Date in respect of an Advance of Term Loans to occur after the Upsize Closing Date, Term Loans shall be made on a non pro rata basis, rather than in accordance with the Commitment Percentage of each Lender, such that after giving effect to such Advance, the outstanding Term Loans of each Lender shall be equal to its Commitment Percentage of all then outstanding Term Loans.

(b) Subject to Section 5.04 (Obligation to Mitigate), each Lender may (without relieving the Borrower of its obligation to repay a Loan in accordance with the terms of this Agreement and the Notes), at its option, fulfill its Commitments with respect to any such Loan by causing any domestic or foreign branch or Affiliate of such Lender to make such Loan.

(c) Unless the Credit Facility Agent has been notified in writing by any Lender prior to a proposed Advance Date that such Lender will not make available to the Credit Facility Agent its portion of the Advance proposed to be made on such date, the Credit Facility Agent may assume that such Lender has made such amounts available to the Credit Facility Agent on such date and the Credit Facility Agent in its sole discretion may, in reliance upon such assumption, make available to the Borrower a corresponding amount. If such corresponding amount is not in fact made available to the Credit Facility Agent by such Lender and the Credit Facility Agent has made such amount available to the Borrower the Credit Facility Agent shall be entitled to recover on demand from such Lender such corresponding amount plus interest on such corresponding amount in respect of each day from the date such corresponding amount was made available by the Credit Facility Agent to the Borrower to the date such corresponding amount is recovered by the Credit Facility Agent at an interest rate per annum equal to the Federal Funds Effective Rate. If such Lender pays such corresponding amount (together with such interest), then such corresponding amount so paid shall constitute such Lender’s Term Loan or Working Capital Loan, as applicable, included in such Advance. If such Lender does not pay such corresponding amount forthwith upon the Credit Facility Agent’s demand, the Credit Facility Agent shall promptly notify the Borrower and the Borrower shall promptly repay such corresponding amount to the Credit Facility Agent plus interest on such corresponding amount in respect of each day from the date such corresponding amount was made available by the Credit Facility Agent to the Borrower to the date such corresponding amount is recovered by the Credit Facility Agent at an interest rate per annum equal to the Base Rate plus the Applicable Margin. If the Credit Facility Agent receives payment of the corresponding amount from each of the Borrower and such Lender, the Credit Facility Agent shall promptly remit to the Borrower such corresponding amount. If the Credit Facility Agent receives payment of interest on such corresponding amount from each of the Borrower and such Lender for an overlapping period, the Credit Facility Agent shall promptly remit to the Borrower the amount of such interest paid by the Borrower for such period. Nothing herein shall be deemed to relieve any Lender from its obligation to fulfill its Commitments hereunder and, for the avoidance of doubt, a Lender that fails to make its portion of any Advance on the due date for such payment hereunder shall be deemed in default of its obligations under Section 2.01 (Term Loans) or Section 2.03 (Working Capital Loans) above, as applicable. Any payment by the Borrower pursuant to this Section 2.06(c) (Funding) shall be without prejudice to any claim the Borrower may have against a Lender that shall have failed to make such payment to the Credit Facility Agent. The failure of any Lender to make available to the Credit Facility Agent its portion of the Advance shall not relieve any other Lender of its obligations, if any, hereunder to make available to the Credit Facility Agent its portion of the Advance on the date of such Advance, but no Lender shall

 

10


be responsible for the failure of any other Lender to make available to the Credit Facility Agent such other Lender’s portion of the Advance on the date of any Advance. A notice of the Credit Facility Agent to any Lender or the Borrower with respect to any amounts owing under this Section 2.06(c) (Funding) shall be conclusive, absent manifest error.

(d) Each Lender shall maintain in accordance with its usual practice and form an account or accounts evidencing the Indebtedness of the Borrower to such Lender resulting from each Loan made by such Lender, including the amounts of principal and interest payable and paid to such Lender from time to time hereunder.

(e) The Credit Facility Agent shall maintain at one of the Credit Facility Agent’s offices (i) a copy of any Lender Assignment Agreement delivered to it pursuant to Section 11.04 (Assignments), and (ii) a register for the recordation of (A) the names and addresses of the Lenders and the Issuing Banks, (B) all the Commitments of, and principal amount of and interest on the Loans owing and paid to, each Lender pursuant to the terms hereof from time to time, (C) the amount, beneficiary and termination date of all outstanding Letters of Credit, (D) the Issuing Bank Limit of each Issuing Bank and (E) amounts received by the Credit Facility Agent from the Borrower and whether such amounts constitute principal, interest, fees or other amounts and each Lender’s or Issuing Bank’s share thereof (the “Register”). The Register shall be available for inspection by the Borrower, any Issuing Bank and any Lender (with respect to such Issuing Bank’s Issuing Bank Limits, Fronting Limits and/or Non-Fronting Limits and such Lender’s Commitments and/or Loans, as applicable) at any reasonable time and from time to time upon reasonable prior notice.

(f) The entries made by the Credit Facility Agent in the Register or the accounts maintained by any Lender shall be conclusive and binding evidence, absent manifest error, of the existence and amounts of the obligations recorded therein; provided that, the failure of any Lender or the Credit Facility Agent to maintain such Register or accounts or any error therein shall not in any manner affect the obligation of the Borrower to repay the Loans in accordance with the terms of this Agreement. In the event of any conflict between the accounts and records maintained by any Lender and the accounts and records of the Credit Facility Agent in respect of such matters, the accounts and records of the Credit Facility Agent shall control, in the absence of manifest error.

(g) In addition to such accounts or records described in clauses (d) and (e) of this Section 2.06 (Funding), the Loans made by each Lender may, upon the request of any Term Lender, be evidenced by a Term Loan Note or Term Loan Notes, in the case of Term Loans, or a Working Capital Loan Note or Working Capital Loan Notes, in the case of Working Capital Loans, in each case, duly executed on behalf of the Borrower and dated the date of any request therefor by a Lender. Each such Note shall have all blanks appropriately filled in, and shall be payable to such Lender and its registered assigns in a principal amount equal to the Term Loan(s) and Working Capital Loan(s) of such Lender; provided that, each Lender may attach schedules to its respective Note(s) and endorse thereon the date, amount and maturity of its respective Loan(s).

Section 2.07 Termination or Reduction of Commitments. (a) (i) All unused Term Loan Commitments, if any, shall be automatically and permanently terminated (without premium or penalty) as of 5:00 p.m. on the last day of the Term Loan Availability Period that is a Business Day and (ii) all then-unused Working Capital Commitments, if any, shall be automatically and permanently terminated (without premium or penalty) as of 5:00 p.m. on the last day of the Working Capital Loan Availability Period that is a Business Day.

 

11


(b) The Borrower may cancel or reduce permanently the whole or any part of the unutilized Term Loan Commitments and/or Working Capital Commitments (together with a corresponding ratable cancellation or reduction of the Issuing Bank Limits for each Issuing Bank by the amount by which the Issuing Bank Limits exceed the Aggregate Working Capital Commitments after giving effect to the cancellation or reduction of unutilized Working Capital Commitments), in either case, in accordance with Section 3.2 (Right of Repayment and Cancellation in Relation to a Single Facility Lender), Section 3.7 (Pro Rata Payment) and Section 3.8 (Reductions and Cancellations of Facility Commitments) of the Common Terms Agreement (provided that, Section 3.8(c) of the Common Terms Agreement shall not apply to a reduction or cancellation of Working Capital Commitments) and upon at least three (3) Business Days’ prior written notice to the Credit Facility Agent (with a copy to any applicable Issuing Bank) and certification by the Borrower to the Credit Facility Agent that the letter of credit capacity under the portion of the Working Capital Commitments to be cancelled or reduced, after taking into account other funding sources irrevocably available to the Obligors, is not required to satisfy any express obligation of either Obligor to provide performance security; provided that, (i) except as provided in Section 2.01 (Term Loans), the Borrower may not cancel or reduce any part of the Contingency Reserve Term Loan Commitments until the Project Phase 2 Completion Date except to the extent any such cancelled or reduced commitments are replaced on a dollar-for-dollar basis with alternative Senior Debt commitments or cash on deposit in the Contingency Reserve Account, (ii) in the event the Borrower cancels or reduces any part, but not all, of the Commitments prior to the Project Phase 1 Completion Date (other than in accordance with Section 6.3 (Replacement Debt) of the Common Terms Agreement), the Borrower shall deliver to the Credit Facility Agent a certification (confirmed in writing by the Independent Engineer) that such cancellation or reduction will not result in the Obligors’ having an insufficient amount of committed or funded capital to fund (on the basis of all other available funds, including funds in the Construction Account and the Contingency Reserve Account, and any remaining Commitments) the remaining expenditures required to achieve the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain and (iii) in the event the Borrower cancels or reduces any part, but not all, of the Commitments after the Project Phase 1 Completion Date (other than in accordance with Section 2.01 (Term Loans) or Section 6.3 (Replacement Debt) of the Common Terms Agreement) and prior to the Project Phase 2 Completion Date (other than in accordance with Section 6.3 (Replacement Debt) of the Common Terms Agreement), the Borrower shall deliver to the Credit Facility Agent a certification (confirmed in writing by the Independent Engineer) that such cancellation or reduction will not result in the Obligors’ having an insufficient amount of committed or funded capital to fund (on the basis of all other available funds, including funds in the Construction Account and the Contingency Reserve Account, and any remaining Commitments) the remaining expenditures required to achieve the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain; provided further that, in accordance with Section 3.8 (Reductions and Cancellations of Facility Commitments) and Section 3.7(b)(i) (Pro Rata Payment) of the Common Terms Agreement and Section 2.3(a) (Payments and Prepayments – Pro Rata Payment of Senior Debt Obligations) of the Common Security and Account Agreement, (A) any such cancellation of

 

12


Working Capital Commitments and Issuing Bank Limits may be made without pro rata cancellation of Facility Debt Commitments under any other Facility Agreements then in effect and (B) the Working Capital Lenders shall not be entitled to pro rata cancellation in the case of a cancellation of Facility Debt Commitments under any other Facility Agreements. Where such cancellation or reduction is to be made pro rata, the applicable Commitments and Issuing Bank Limits (if such cancellation or reduction is with respect to Working Capital Commitments) shall be automatically and permanently reduced pro rata among all Lenders and Issuing Banks holding such Commitments and Issuing Bank Limits in accordance with their respective Commitment Percentages. Any such partial cancellation or reduction (x) of Term Loan Commitments pursuant to this Section 2.07(b) shall be in a minimum amount of $5,000,000 and (y) of Working Capital Commitments shall be in an amount of $5,000,000 or an integral multiple of $5,000,000 in excess thereof (or, in each case, if less the remaining amount of such Commitment). From the effective date of any such reduction or cancellation, the Commitment Fees shall be computed on the undrawn portion of the applicable Commitments as so reduced or cancelled.

(c) On the date of incurrence of any Replacement Debt in accordance with Section 6.3 (Replacement Debt) of the Common Terms Agreement incurred to replace all or any part of the Term Loan, the Term Loan Commitments of the Term Lenders shall be reduced in accordance with Section 3.8(a) (Reductions and Cancellations of Facility Commitments) of the Common Terms Agreement; provided that, the Borrower shall be deemed to have repaid Term Loans and cancelled Facility Debt Commitments on a pro rata basis by applying the proceeds of such Replacement Debt first to repay any outstanding Term Loans in accordance with Section 4.16(c) (Pro Rata Treatment), and, to the extent any Replacement Debt proceeds remain, secondly to cancel Term Loan Commitments that subsequently remain available to be drawn on a pro rata basis without regard to whether such Term Loans or Term Loan Commitments are with respect to any Initial Term Loan Commitments or Incremental Term Loan Commitments. On the date of incurrence of any Replacement Debt in accordance with Section 6.3 (Replacement Debt) of the Common Terms Agreement, no pro rata repayment of Working Capital Loans or cancellations of Working Capital Commitments shall be required to be made by the Obligors unless such Replacement Debt has been incurred to replace all or any part of the Working Capital Loans and/or Working Capital Commitments.

(d) The Borrower shall have the right to replace any Non-Consenting Lender on a non-pro rata basis, pursuant to Section 5.04(b) (Obligation to Mitigate).

(e) All unused Commitments, if any, shall be terminated upon the occurrence and Continuance of a Loan Facility Event of Default if required pursuant to Section 9.02 (Acceleration Upon Bankruptcy) or Section 9.03 (Action Upon Event of Default) in accordance with the terms thereof.

Section 2.08 Incremental Commitments.

(a) The Borrower may from time to time, by written notice to the Credit Facility Agent (a “Working Capital Commitment Increase Notice”), request increases in the Working Capital Commitments (together with any applicable corresponding increases in the Issuing Bank Limits) of the relevant Working Capital Lender, Issuing Bank or by any other Person that is an Eligible

 

13


Assignee or satisfies the rating requirement set forth in the definition of “Issuing Bank,” as applicable (each, a “Working Capital Commitment Increase”), up to an aggregate principal amount not to exceed the maximum amount of Working Capital Debt permitted pursuant to Section 6.2(a) (Working Capital Debt) of the Common Terms Agreement.

(b) The Working Capital Commitment Increase Notice shall specify (i) the date on which the Borrower proposes that such Working Capital Commitment Increase shall be effective, which shall be a date not less than thirty (30) days after the date on which such notice is delivered to the Credit Facility Agent (or, subject to clause (c)(iii)(E) below, such shorter period of time as agreed by the Incremental Lender/Issuing Banks (as defined below) participating in such Working Capital Commitment Increase), (ii) the amounts of the Working Capital Commitment Increase (including any proposed increase in Non-Fronting Limit or Fronting Limit of an Issuing Bank) and (iii) the identity of each Working Capital Lender, Issuing Bank or other Person that is an Eligible Assignee or satisfies the rating requirement set forth in the definition of “Issuing Bank,” as applicable (each, an “Incremental Lender/Issuing Bank”) to whom the Borrower proposes any portion of the Working Capital Commitment Increase be allocated and the amounts of such allocations; provided that, any Working Capital Lender, Issuing Bank or other Person approached to provide all or a portion of the Working Capital Commitment Increase may elect or decline, in its sole and absolute discretion, to participate.

(c) Each Working Capital Commitment Increase shall become Working Capital Commitments, Issuing Bank Limits, Non-Fronting Limits or Fronting Limits (as applicable) (or, in the case of an increase in the commitment of an existing Working Capital Lender or Issuing Bank, an increase in such Working Capital Lender’s or Issuing Bank’s applicable Working Capital Commitment, Issuing Bank Limit, Non-Fronting Limit or Fronting Limit (as applicable)) under this Agreement pursuant to an amendment (such amendment, an “Incremental Amendment”) to this Agreement executed by the Borrower, the Credit Facility Agent and each Incremental Lender/Issuing Bank (with the consent of no other Working Capital Lender being required) which provides solely for (i) the increase in the applicable Working Capital Commitments, Issuing Bank Limits, Non-Fronting Limits or Fronting Limits (as applicable) proposed in the applicable Working Capital Commitment Increase Notice and consented to by the applicable Incremental Lender/Issuing Bank, (ii) amendments required to reflect the relative unfunded Commitments of the Incremental Lenders/Issuing Banks and (iii) the joinder of each Incremental Lender/Issuing Bank that is not already an existing Working Capital Lender or Issuing Bank party to this Agreement. The effectiveness of any Incremental Amendment shall be subject solely to the conditions that (A) no Loan Facility Event of Default or Unmatured Loan Facility Event of Default shall exist on such date of effectiveness before or after giving effect to such Working Capital Commitment Increase, (B) each Incremental Lender/Issuing Bank that is not already a Working Capital Lender shall be entitled to receipt of any required reliance letters in respect of the legal opinions provided to the Credit Facility Agent pursuant to Section 4.1(f) (Conditions to Initial Closing Date and Initial Advance – Opinions from Counsel) of the Common Terms Agreement or Section 4.2(f) (Conditions to Upsize Closing Date – Opinions from Counsel) of the Common Terms Agreement, as applicable, (C) since the time of the financial statements most recently provided pursuant to Section 10.1(a) (Accounting, Financial and Other Information) of the Common Terms Agreement no developments have occurred which, individually or in the aggregate have resulted in or could reasonably be expected to result in a Material Adverse Effect,

 

14


(D) each Incremental Lender/Issuing Bank who is not already a Working Capital Lender or Issuing Bank is reasonably acceptable to the Credit Facility Agent and each Issuing Bank and (E) the Intercreditor Agent has received, at least three (3) Business Days before the effectiveness of such Incremental Amendment, a certificate from the Borrower that (1) identifies each holder of Working Capital Commitments (after giving effect to the applicable Working Capital Commitment Increase) and (2) attaches a copy of the proposed Incremental Amendment.

Section 2.09 Use of Proceeds.

(a) The Borrower shall be permitted to use the proceeds of:

(i) Term Loans funded from the Base Term Loan Commitment solely: (A) to pay Project Costs relating to the Project Facilities, including the payment of Permitted Completion Costs and, on the Project Phase 1 Completion Date and the Project Phase 2 Completion Date, funding the Senior Facilities Debt Service Reserve Account and the Contingency Reserve Account (to the extent not funded with one or more Letters of Credit or Acceptable Debt Service Reserve LCs), (B) to make Authorized Investments, (C) to reimburse Drawstop Equity Contributions previously made in respect of the Project Facilities in accordance with Section 11.2(c) (Certain Restricted Payments) of the Common Terms Agreement and Section 4.5(d) (Deposits and Withdrawals – Construction Account) of the Common Security and Account Agreement, and (D) to pay transaction costs, fees and expenses in connection with the closing of the Initial Senior Debt, the closing of the Incremental Senior Debt and the Development; and

(ii) Term Loans funded from the Contingency Reserve Term Loan Commitment solely (A) prior to the Project Phase 2 Completion Date, to fund the Contingency Reserve Account for application to pay Project Costs relating to the Project Facilities and (B) on the Project Phase 2 Completion Date, to fund the withdrawals and transfers contemplated by Section 14.4 (Project Phase 2 Completion Date Waterfall) of the Common Terms Agreement.

(b) The Borrower shall be permitted to use the Letters of Credit and the proceeds of Working Capital Loans solely for working capital purposes of the Obligors, including (i) to satisfy the Obligors’ credit support (and related mark to market) obligations under the Material Project Agreements and/or other contracts, including such obligations related to purchases of natural gas and any costs and expenses related to the supply or transport of natural gas by the Obligors and (ii) to fund reserve requirements; provided that (A) prior to the Project Phase 1 Completion Date, with respect to all proceeds of Working Capital Loans and the issuance of Letters of Credit and (B) after the Project Phase 1 Completion Date and prior to the Project Phase 2 Completion Date, with respect to proceeds of Working Capital Loans and the issuance of Letters of Credit in an amount up to the P2 WCF Sublimit, the Borrower shall be permitted to use such proceeds of Working Capital Loans and the issuance of Letters of Credit solely (I) for collateralization (and related mark to market) of, including the posting of Letters of Credit, or purchases of natural gas and any costs and expenses related to the supply or transport of natural gas by the Obligors (including for testing or operations) and (II) to fund reserve requirements; provided further that, the Borrower shall not borrow amounts under the Working Capital Facility or use the proceeds of

 

15


Working Capital Loans to meet any requirement under any other Senior Debt Instrument governing the Working Capital Debt that the Borrower reduce the principal amount relating to any revolving loans under such other Senior Debt Instrument to $0 for a period of at least five (5) consecutive Business Days at least once per calendar year (it being acknowledged and agreed that the foregoing shall not limit the utilization by the Borrower of other Indebtedness that is permitted to be incurred pursuant to Section 12.14 (Limitation on Indebtedness) of the Common Terms Agreement for such purposes to the extent the terms and conditions of such Indebtedness permit such utilization). For the avoidance of doubt, Working Capital Loans shall not be used for the payment of Project Costs.

ARTICLE III

LETTERS OF CREDIT

Section 3.01 Letters of Credit.

(a) Subject to the terms and conditions set forth herein and, as applicable, the terms and conditions set forth in the Common Terms Agreement, during the Working Capital Loan Availability Period, the Borrower may (but is not required to), deliver to (1) the Credit Facility Agent (which shall promptly distribute copies thereof to the Working Capital Lenders), (2) the Issuing Bank designated by the Borrower (with the consent of such Issuing Bank in its sole discretion) with respect to Fronted Letters of Credit and (3) each Issuing Bank with a Non-Fronting Limit with respect to Non-Fronted Letters of Credit, a letter of credit request substantially in the form of Schedule B-3 to the Common Terms Agreement (Issuance Request Form (Letters of Credit)) or such other form as requested by the Borrower and reasonably acceptable to the applicable Issuing Bank (a “Request for Issuance”) for the issuance, extension, modification or amendment of a Letter of Credit from time to time during the Working Capital Loan Availability Period. Each Request for Issuance shall include (i) the date (which shall be a Business Day, but in no event later than the date that occurs five (5) Business Days prior to the Final Maturity Date) of issuance of such Letter of Credit (or such extension, modification or amendment) and the stated expiry date thereof (which will be consistent with Section 3.01(d) (Letters of Credit)), (ii) the proposed amount of such Letter of Credit, (iii) the intended beneficiary of such Letter of Credit, (iv) a description of the intended use of such Letter of Credit and (v) whether such Letter of Credit is to be a Fronted Letter of Credit or a Non-Fronted Letter of Credit. Each Request for Issuance shall be irrevocable unless modified or rescinded by the Borrower not less than three (3) Business Days prior to the proposed date of issuance (or extension, modification or amendment) specified therein.

(b) The Borrower may request Letters of Credit up to the lesser of (i) an aggregate amount for all requested and issued Letters of Credit of the aggregate of the Issuing Bank Limits of all Issuing Banks and (ii) the Aggregate Working Capital Commitments; provided that, in each case, no Issuing Bank shall be required to issue any Letter of Credit or any amendment to increase the available balance of any Letter of Credit if, after such issuance or amendment, (A) the aggregate Working Capital Commitment Exposure for all Working Capital Lenders shall exceed the Aggregate Working Capital Commitments, (B) the LC Exposure of such Issuing Bank with a Fronting Limit shall exceed its Fronting Limit, (C) the LC Exposure of such Issuing Bank with a Non-Fronting Limit shall exceed its Non-Fronting Limit, (D) the LC Exposure of such Issuing

 

16


Bank shall exceed its Issuing Bank Limit or (E) the Working Capital Commitment Exposure of such Issuing Bank shall exceed its Working Capital Commitment in its capacity as a Working Capital Lender. For the avoidance of doubt, subject to compliance with the foregoing requirements and Sections 3.01(a) and 3.01(f) (Letters of Credit), the Borrower may request Fronted Letters of Credit from an Issuing Bank with a Fronting Limit up to the Issuing Bank’s full Fronting Limit.

(c) Promptly after its receipt of a Request for Issuance, the Issuing Bank will confirm with the Credit Facility Agent (in writing) that the Credit Facility Agent has received a copy of such Request for Issuance from the Borrower and, if not, the Issuing Bank will provide the Credit Facility Agent with a copy thereof. Unless the Issuing Bank has received notice (in writing) from the Credit Facility Agent (including at the request of any Working Capital Lender) no later than three (3) Business Days prior to the proposed date of issuance (or extension, modification or amendment) (i) directing the Issuing Bank not to issue (or extend, amend or modify) such Letter of Credit as a result of the limitations set forth in Section 3.01(b) (Letters of Credit), or (ii) that one or more of the applicable conditions precedent in Section 7.04 (Conditions to Each Working Capital Advance) is not then satisfied or waived, then (A) the applicable Issuing Bank shall issue (or extend, modify or amend) each Letter of Credit not later than 1:00 p.m. on the later of (1) the proposed date of issuance (or extension, modification or amendment) specified in such Request for Issuance and (2) three (3) Business Days after the receipt of the Request for Issuance (taking into account that any Request for Issuance received after 1:00 p.m. on any Business Day will be deemed received on the next Business Day), and (B) such issuance (or extension, modification or amendment) shall be subject to the terms and conditions hereof, including fulfillment of the applicable conditions precedent and the other requirements set forth herein (including Sections 3.01(a) and 3.01(f) (Letters of Credit)). An Issuing Bank that issues (or extends, amends or modifies) a requested Letter of Credit pursuant to this Section 3.01 (Letters of Credit) shall issue (or extend, amend or modify) such Letter of Credit to the Borrower or directly to the intended beneficiary and shall provide notice and a copy thereof to the Intercreditor Agent and the Credit Facility Agent, which, in the case of a Fronted Letter of Credit, shall promptly furnish copies thereof to the Working Capital Lenders, and to the extent that such Letter of Credit was issued directly to the intended beneficiary, such Issuing Bank shall provide notice and a copy thereof to the Borrower.

(d) Each Letter of Credit shall expire no later than the earlier of (i) one year from the date of issuance of such Letter of Credit and (ii) five (5) Business Days prior to the Working Capital Loan Termination Date. Each Letter of Credit may, if requested by the Borrower, provide that it will be automatically extended for a stated period of time at the end of its then-scheduled expiration date and each successive expiration date (but in any event shall not be extended for longer than one year from the date of effectiveness of each such extension or beyond five (5) Business Days prior to the Working Capital Loan Termination Date) unless the Issuing Bank that issued the Letter of Credit notifies the beneficiary thereof no later than thirty (30) days prior to such expiration date that such Issuing Bank elects not to renew or extend such Letter of Credit. In no event shall the Working Capital Lenders have any obligation to pay any amount to (or for the account of) any Issuing Bank or any other Person, in respect of a drawing under a Letter of Credit that occurs after the Final Maturity Date.

 

17


(e) Notwithstanding anything in this Agreement to the contrary, no Issuing Bank will have any obligation to issue, or extend the expiry date of, any Letter of Credit if (i) any judgment, order, or decree of any Governmental Authority or arbitrator shall by its terms purport to enjoin or restrain such Issuing Bank from issuing, or extending the expiry date of, such Letter of Credit or

(ii) any Government Rule or any directive (whether or not having the force of law) from any Governmental Authority with jurisdiction over such Issuing Bank shall prohibit, or direct that such Issuing Bank refrain from, the issuance of new letters of credit or the extension of the expiry date of issued letters of credit generally or the issuance, or extension of the expiry date of, a Letter of Credit specifically or shall impose upon such Issuing Bank with respect to such Letter of Credit any restriction, reserve, or capital requirement, or shall impose upon such Issuing Bank any loss, cost, or expense. Each Issuing Bank shall provide the Borrower with prompt notice of the occurrence of any event described in this Section 3.01(e) (Letters of Credit) not later than two (2) Business Days after obtaining knowledge of the occurrence of any such event.

(f) The Borrower may request that a Letter of Credit be a Fronted Letter of Credit or a Non-Fronted Letter of Credit; provided that, (i) the Borrower may only request Fronted Letters of Credit from an Issuing Bank that is specified in this Agreement as having a Fronting Limit and who has consented to issue such Fronted Letter(s) of Credit in accordance with Section 3.01(a) (Letters of Credit), and (ii) if the Borrower wishes to request Non-Fronted Letters of Credit, the Borrower shall determine the specific aggregate amount to be covered by such Letters of Credit to be provided to a specific beneficiary (the “Non-Fronted LC Amount”), and it shall make requests for Non-Fronted Letters of Credit simultaneously to all the Issuing Banks under this Agreement such that the aggregate amount of all such Non-Fronted Letters of Credit issued to such beneficiary is equal to the Non-Fronted LC Amount and the amount of the Non-Fronted Letter of Credit of each individual Issuing Bank is equal to its Commitment Percentage of the Non-Fronted LC Amount. No Working Capital Lender is required to participate in the extension of credit resulting from the issuance (or extension, modification or amendment) of a Non-Fronted Letter of Credit issued by an Issuing Bank other than itself. Each Working Capital Lender severally agrees with each Issuing Bank to participate in an amount equal to its Commitment Percentage in the extension of credit resulting from the issuance (or extension, modification or amendment) of a Fronted Letter of Credit by such Issuing Bank and each drawing of the LC Available Amounts thereunder, in the manner and the amount provided in Section 3.02 (Reimbursement to Issuing Banks), and the issuance of such Fronted Letter of Credit shall be deemed to be a confirmation by the Issuing Bank and each Working Capital Lender of such participation in such amount; provided that, no Working Capital Lender shall be required to participate in a Fronted Letter of Credit to the extent such Working Capital Lender’s Working Capital Commitment Exposure would exceed its Working Capital Commitment as a result of such participation.

(g) In addition to the date of issuance, stated expiry date, amount, beneficiary, intended use and request for a Fronted Letter of Credit or Non-Fronted Letter of Credit specified in the applicable Request for Issuance, each Letter of Credit shall provide (unless the Borrower specifies otherwise in such Request for Issuance) for:

(i) payment in immediately available funds in US Dollars on a Business Day;

(ii) multiple drawings and partial drawings;

 

18


(iii) applicability of the International Standby Practices 1998, International Chamber of Commerce Publication No. 590 (1998) (“ISP98”), Uniform Customs and Practice for Documentary Credits, International Chamber of Commerce Publication No. 600 (2007) (“UCP 600”), or such other rules as the Borrower and the applicable Issuing Bank shall agree, and shall, as to matters not governed by ISP98, UCP 600 or such other rules, be governed and construed in accordance with the laws of the State of New York and applicable U.S. federal law;

(iv) a drawing by the beneficiary of the full available amount thereof if either (A) the Issuing Bank that issued the Letter of Credit ceases to satisfy the minimum credit ratings for an Issuing Bank hereunder (as set forth in the definition of “Issuing Bank” in Exhibit A (Definitions)) and such Letter of Credit has not been replaced by an Issuing Bank satisfying such minimum credit ratings within thirty (30) days or such shorter number of days as required under the document, if any, with respect to which such Letter of Credit is issued; provided that, the right to draw under this clause (A) shall only be included in the applicable Letter of Credit to the extent required under such document with respect to which such Letter of Credit is issued or (B) the Issuing Bank that issued the Letter of Credit notifies the Borrower (which shall promptly notify the beneficiary) no later than 60 days prior to the then-scheduled expiration date that such Issuing Bank elects not to extend such Letter of Credit; and

(v) in the case of a Non-Fronted Letter of Credit, the beneficiary will be required to certify that it is making a pro rata draw with all other Letters of Credit issued in favor of such beneficiary in respect of a Non-Fronted LC Amount based on the percentage of such Non-Fronted Letter of Credit to Non-Fronted LC Amount as notified to the beneficiary by the Borrower.

(h) Following the Upsize Closing Date, no Working Capital Lender may be appointed as an Issuing Bank without its prior written consent.

Section 3.02 Reimbursement to Issuing Banks.

(a) An Issuing Bank shall give the Credit Facility Agent, the Collateral Agent, the Borrower and each of the Working Capital Lenders prompt notice of any payment made by such Issuing Bank in accordance with the terms of any Letter of Credit issued by such Issuing Bank (an “LC Payment Notice”) no later than 10:00 a.m. on the Business Day immediately succeeding the date of such payment by such Issuing Bank.

(b) Upon delivery to the Borrower of an LC Payment Notice on or before 10:00 a.m., New York City time, on the Business Day immediately succeeding the date of such payment by an Issuing Bank, the Borrower shall either (i) on or before 12:00 noon on such Business Day, reimburse such Issuing Bank for such payment (an “LC Reimbursement Payment”) by paying to the Credit Facility Agent, for the account of such Issuing Bank, an amount equal to the payment made by such Issuing Bank plus interest on such amount at a rate per annum equal to the Base Rate plus the Applicable Margin for Base Rate Loans (provided that, if an Issuing Bank delivers an LC Payment Notice to the Borrower after 10:00 a.m. New York City time on the Business Day immediately succeeding the date of payment by such Issuing Bank, the Borrower shall make the

 

19


LC Reimbursement Payment on or before 12:00 noon New York City time on the next succeeding Business Day) or (ii) (A) provide written notice to such Issuing Bank and the Credit Facility Agent electing to have the reimbursement obligation converted into an LC Loan in accordance with Sections 3.02(c) and (f) (Reimbursement to Issuing Banks) or (B) not make the LC Reimbursement Payment as required under Section 3.02(b)(i) (Reimbursement to Issuing Banks), in which case, in the case of this clause (ii), such reimbursement obligation shall automatically convert to an LC Loan as of such time; provided that, no Loan Facility Event of Default shall have occurred and been Continuing as of the time of the applicable payment made under the Letter of Credit. An Issuing Bank’s failure to provide an LC Payment Notice shall not relieve the Borrower of its obligation to reimburse such Issuing Bank for any payment it makes under any Letter of Credit. In the case of any Non-Fronted Letters of Credit issued with respect to a specific Non-Fronted LC Amount, the Borrower may not elect to make an LC Reimbursement Payment and/or convert a reimbursement obligation into a LC Loan for some but not all the Issuing Banks providing Non- Fronted Letters of Credit with respect to such Non-Fronted LC Amount.

(c) If the Borrower fails to make the LC Reimbursement Payment as required under Section 3.02(b) (Reimbursement to Issuing Banks) or provides written notice to such Issuing Bank and the Credit Facility Agent electing to have the reimbursement obligation converted into an LC Loan, such reimbursement obligation shall automatically convert to an LC Loan; provided that, no Loan Facility Event of Default shall have occurred and been Continuing as of the time of the applicable payment made under the Letter of Credit. If such LC Loan or failure to make the LC Reimbursement Payment relates to a Fronted Letter of Credit, the Credit Facility Agent shall promptly notify each of the Working Capital Lenders of the amount of its share of the payment made under such Fronted Letter of Credit, which shall be such Working Capital Lender’s Commitment Percentage of such amount paid by such Issuing Bank (the “Working Capital Lender Payment Notice”). Subject to Section 3.01(f) (Letters of Credit), each Working Capital Lender hereby severally agrees to pay the amount specified in the Working Capital Lender Payment Notice in immediately available funds to the Credit Facility Agent for the account of such Issuing Bank with respect to a Fronted Letter of Credit plus interest on such amount at a rate per annum equal to the Federal Funds Effective Rate from the date of such payment by such Issuing Bank to the date of payment to such Issuing Bank by such Working Capital Lender. Each Working Capital Lender shall make such payment by not later than 4:00 p.m. New York City time on the date it received the Working Capital Lender Payment Notice (if such notice is received at or prior to 1:00 p.m. New York City time) and before 12:00 noon New York City time on the next succeeding Business Day following such receipt (if such notice is received after 1:00 p.m. New York City time). In the case of Fronted Letters of Credit, each Working Capital Lender shall severally indemnify and hold harmless such Issuing Bank from and against any and all losses, liabilities (including liabilities for penalties), actions, suits, judgments, demands, costs, and expenses (including reasonable attorneys’ fees and expenses) resulting from any failure on the part of such Working Capital Lender to provide, or from any delay in providing, the Credit Facility Agent for the account of such Issuing Bank with its Commitment Percentage of the amount paid under the Fronted Letter of Credit but no such Working Capital Lender shall be so liable for any such failure on the part of or caused by any other Working Capital Lender or the willful misconduct or gross negligence, as determined by a court of competent jurisdiction by a final and non-appealable order, of the Credit Facility Agent. Each Working Capital Lender’s obligation to make each such payment to the Credit Facility Agent for the account of the applicable Issuing Bank in the case of

 

20


payments made in respect of a Fronted Letter of Credit shall be several and not joint and shall not be affected by (i) the occurrence or continuance of any Loan Facility Event of Default, (ii) the failure of any other Working Capital Lender to make any payment under this Section 3.02 (Reimbursement to Issuing Banks), or (iii) the date of the drawing under the applicable Letter of Credit issued by the applicable Issuing Bank; provided that, such drawing occurs prior to the earlier of (A) the Final Maturity Date or (B) the latest date allowed for presentation of documents under the applicable Fronted Letter of Credit. Each Working Capital Lender further agrees that each such payment shall be made without any offset, abatement, withholding or reduction whatsoever.

(d) The Credit Facility Agent shall pay to the applicable Issuing Bank in immediately available funds the amounts paid in respect of a Fronted Letter of Credit pursuant to Section 3.02(b) (Reimbursement to Issuing Banks) and Section 3.02(c) (Reimbursement to Issuing Banks) before the close of business on the day such payment is received; provided that, any amount received by the Credit Facility Agent that is due and owing to such Issuing Bank and remains unpaid to such Issuing Bank on the date of receipt shall be paid on the next succeeding Business Day with interest payable at the Federal Funds Effective Rate.

(e) For so long as any Working Capital Lender is a Defaulting Lender under clause (a) of the definition thereof, such Defaulting Lender’s participation in LC Exposure shall be reallocated in accordance with Section 4.18(b) (Defaulting Lenders).

(f) Each payment made by a Working Capital Lender under clause (c) above shall constitute an LC Loan deemed made by such Working Capital Lender to the Borrower on the date of such payment by an Issuing Bank under a Fronted Letter of Credit issued by such Issuing Bank. All such payments by the Working Capital Lenders in respect of any one such payment by such Issuing Bank shall constitute a single LC Loan hereunder. Each payment made by an Issuing Bank in respect of a Non-Fronted Letter of Credit that is not reimbursed by the Borrower or that is converted into an LC Loan by notice from the Borrower pursuant to clause (c) above shall constitute an LC Loan deemed made by such Issuing Bank in its capacity as a Working Capital Lender. LC Loans that are converted to SOFR Loans in respect of Non-Fronted Letters of Credit with respect to a specific Non-Fronted LC Amount shall constitute a single SOFR Loan for the purposes of Section 4.05(e) (Interest Rates) hereunder. Each LC Loan initially shall be a Base Rate Loan.

Section 3.03 Obligations Absolute. The payment obligations of each Working Capital Lender under Section 3.02(c) (Reimbursement to Issuing Banks) and of the Borrower under this Agreement in respect of any payment under any Letter of Credit and any LC Loan shall be unconditional and irrevocable (subject only to the Borrower’s and each Working Capital Lender’s right to bring suit against an Issuing Bank pursuant to Section 3.04 (Liability of the Issuing Banks and the Working Capital Lenders) following the reimbursement of such Issuing Bank for any such payment), and shall be paid strictly in accordance with the terms of this Agreement under all circumstances, including the following circumstances:

(a) any lack of validity or enforceability of any Finance Document or any other agreement or instrument relating thereto or to such Letter of Credit;

 

21


(b) any amendment or waiver of, or any consent to departure from, all or any of the Finance Documents;

(c) the existence of any claim, set-off, defense or other right which the Borrower may have at any time against any beneficiary, or any transferee, of such Letter of Credit (or any Persons for whom any such beneficiary or any such transferee may be acting), any Issuing Bank, or any other Person, whether in connection with this Agreement, the transactions contemplated herein or by such Letter of Credit, or any unrelated transaction;

(d) any statement or any other document presented under such Letter of Credit proving to be forged, fraudulent, invalid or insufficient in any respect or any statement therein being untrue or inaccurate in any respect;

(e) payment in good faith by an Issuing Bank under any Letter of Credit issued by such Issuing Bank against presentation of documents that do not comply with the terms of such Letter of Credit; or

(f) any other circumstance or happening whatsoever, whether or not similar to any of the foregoing.

Section 3.04 Liability of the Issuing Banks and the Working Capital Lenders. The Borrower assumes all risks of the acts and omissions of any beneficiary or transferee of any Letter of Credit, and none of the Credit Facility Agent, the Issuing Banks, the Working Capital Lenders nor any of their respective Related Parties shall be liable or responsible for (a) the use that may be made of such Letter of Credit or any acts or omissions of any beneficiary or transferee thereof in connection therewith; (b) the validity, sufficiency or genuineness of documents, or of any endorsement thereon, even if such documents should prove to be in any or all respects invalid, insufficient, fraudulent or forged; (c) payment by the applicable Issuing Bank against presentation of documents that do not comply with the terms of such Letter of Credit, including failure of any documents to bear any reference or adequate reference to such Letter of Credit; or (d) any other circumstances whatsoever in making or failing to make payment under such Letter of Credit; provided that, in each case, payment by the applicable Issuing Bank shall not have constituted gross negligence or willful misconduct as determined by a court of competent jurisdiction by a final and non-appealable order, in which event the Borrower and each Working Capital Lender shall have the right to bring suit against an Issuing Bank, and such Issuing Bank shall be liable to the Borrower and any Working Capital Lender, to the extent of any direct, as opposed to consequential, damages suffered by the Borrower or such Working Capital Lender caused by such Issuing Bank’s willful misconduct or gross negligence as determined by a court of competent jurisdiction by a final and non-appealable order, including such Issuing Bank’s willful failure to make timely payment under such Letter of Credit following the presentation to it by the beneficiary thereof of documents which strictly comply with the terms and conditions of such Letter of Credit.

Section 3.05 Resignation as an Issuing Bank. Any Issuing Bank may, upon no less than thirty (30) days’ prior written notice to the Borrower (with a copy to the Credit Facility Agent, to be distributed to each Working Capital Lender) resign as an Issuing Bank, effective upon the appointment of a successor Issuing Bank in accordance with this Section 3.05 (Resignation as an Issuing Bank). In the event of any such resignation as an Issuing Bank, the Borrower shall be

 

22


entitled to appoint a successor Issuing Bank hereunder from among the Working Capital Lenders (provided that, the Borrower may not so appoint any Working Capital Lender if, as a result of such appointment, such Working Capital Lender’s (a) Working Capital Commitment Exposure would exceed its Working Capital Commitment or (b) LC Exposure would exceed its Issuing Bank Limit, Fronting Limit or Non-Fronting Limit, as applicable) who meet the requirements hereunder to be an Issuing Bank; provided that, no failure by the Borrower to appoint any such successor shall affect the resignation of any Issuing Bank. If any Working Capital Lender resigns as an Issuing Bank, it shall retain all the rights, powers, privileges and duties of an Issuing Bank hereunder with respect to all Letters of Credit that it issued, including Letters of Credit outstanding as of the effective date of its resignation as an Issuing Bank and all LC Exposure with respect thereto (including the right to require the Working Capital Lenders to make LC Loans or fund participations in Letters of Credit). Upon the appointment of a successor Issuing Bank and such successor Issuing Bank’s acceptance, in writing, of the appointment and agreement to be bound by all of the terms and conditions contained in this Agreement and the other Finance Documents binding on it in such capacity, such successor shall succeed to and become vested with all of the rights, powers, privileges and duties of the Issuing Bank as the case may be and the successor Issuing Bank shall issue letters of credit in substitution for the Letters of Credit, if any, outstanding at the time of such succession or make other arrangements satisfactory to the applicable resigning Issuing Bank to effectively assume the obligations of such Issuing Bank with respect to such Letters of Credit.

Section 3.06 Non-Fronted Letters of Credit. The Borrower agrees that in the event that it has provided any Non-Fronted Letter of Credit in respect a Non-Fronted LC Amount, it shall instruct the beneficiary thereof to draw on such Non-Fronted Letter of Credit pro rata among all Non-Fronted Letters of Credit issued in respect of such Non-Fronted LC Amount. In the event that the Borrower has funded the Senior Facilities Debt Service Reserve Account using Non-Fronted Letters of Credit from each Issuing Bank, the Collateral Agent hereby agrees (without the need for any further action or instruction from any Senior Creditors) to draw on such Non-Fronted Letters of Credit only on a pro rata basis as notified by the Borrower to the Collateral Agent or, failing such notification, as provided to the Collateral Agent by the Credit Facility Agent on request.

Section 3.07 Reinstatement of Letters of Credit. The available balance of each Letter of Credit shall be reduced by the amount of any payment made by the applicable Issuing Bank on a drawing thereunder. Once so reduced, the available balance of such Letter of Credit may only be reinstated upon and to the extent of any reimbursement by the Borrower of such drawing or, if reimbursement of such drawing is made through LC Loans, upon and to the extent of payment by the Borrower of the LC Loans corresponding to such drawing, in each case, pursuant to Section 3.02 (Reimbursement to Issuing Banks). At least one (1) Business Day prior to the date of any such reinstatement of a Letter of Credit, the Borrower shall deliver to such Issuing Bank and the Credit Facility Agent a written request for reinstatement signed by an Authorized Officer of the Borrower and in form and substance satisfactory to such Issuing Bank. Upon the effectiveness of any such reinstatement, such Issuing Bank shall notify the Borrower, the Credit Facility Agent and the beneficiary of the reinstated Letter of Credit and shall indicate in such notice the new available balance of such Letter of Credit.

 

23


Section 3.08 Existing Letters of Credit. All Existing Letters of Credit shall be deemed to have been issued pursuant hereto, and from and after the Initial Closing Date shall be subject to and governed by the terms and conditions hereof. Notwithstanding anything to the contrary contained herein, City National Bank shall be an Issuing Bank hereunder only with respect to the Existing Letters of Credit issued by it and shall have no obligation or further commitment to issue any additional Letters of Credit pursuant to this Agreement.

ARTICLE IV

REPAYMENTS, PREPAYMENTS, INTEREST AND FEES

Section 4.01 Repayment of Term Loan Advances.

(a) The Borrower unconditionally and irrevocably promises to pay to the Credit Facility Agent for the ratable account of each Term Lender the aggregate outstanding principal amount of the Term Loans on each CTA Payment Date (i) beginning on the First Repayment Date, in accordance with the Initial Amortization Schedule and (ii) beginning on the First Upsize Repayment Date, in accordance with the Upsize Amortization Schedule.

(b) On the Project Phase 2 Completion Date, the Credit Facility Agent shall generate and promptly provide to the Intercreditor Agent and the Borrower a revised Amortization Schedule (in respect of which it shall have consulted with the Borrower) based on the total Term Loans outstanding on the Project Phase 2 Completion Date (the “Upsize Amortization Schedule”) (after taking account of any repayments made and changes to the amortization schedule previously made in accordance with Section 4.01(b) (Repayment of Term Loan Advances) below).

(c) In addition, following the making of any prepayments pursuant to this Agreement or Section 3.1 (CTA Payment Dates) of the Common Terms Agreement, including in connection with the incurrence of Replacement Debt, the Credit Facility Agent shall, of its own motion or as reasonably requested by the Borrower, generate and promptly provide to the Intercreditor Agent and the Borrower a revised Amortization Schedule (in respect of which it shall have consulted with the Borrower) and if any such prepayments are made or any such Replacement Debt is incurred prior to the Project Phase 2 Completion Date, the then current Initial Term Loan Amount shall be reduced by an amount equal to (i) the amount of the Term Loans so refinanced multiplied by (ii) the percentage determined by dividing (A) the Initial Term Loan Amount (as in effect at the Upsize Closing Date) by (B) the aggregate amount of the Term Loan Commitments (including Term Loans outstanding under such Commitments) as of the Upsize Closing Date. In any of the instances described above, such revised Amortization Schedule shall be delivered prior to the next Quarterly Payment Date and prepared in a manner that is consistent with the principles used to prepare the original applicable Amortization Schedule. Any failure by the Credit Facility Agent to provide any revised Amortization Schedule as required pursuant to this Section 4.01 (Repayment of Term Loan Advances) shall not affect the Borrower’s obligations to pay the Term Loans in accordance with this Agreement.

 

24


(d) The repayment of principal by the Borrower for the Term Loans shall commence on the earlier of (such earlier date, the “First Repayment Date”):

(i) the first Quarterly Payment Date (or, if such date is not a Business Day, the Business Day immediately prior to such Quarterly Payment Date) occurring more than three calendar months following the Project Phase 1 Completion Date; and

(ii) the Phase 1 LNG Facility Date Certain.

(e) The repayment of principal by the Borrower based on the Upsize Amortization Schedule shall commence on the earlier of (such earlier date, the “First Upsize Repayment Date”):

(i) the first Quarterly Payment Date (or, if such date is not a Business Day, the Business Day immediately prior to such Quarterly Payment Date) occurring more than three calendar months following the Project Phase 2 Completion Date; and

(ii) the Phase 2 LNG Facility Date Certain.

(f) Notwithstanding anything to the contrary set forth in Section 4.01(a) (Repayment of Term Loan Advances) above, the final principal repayment installment on the Final Maturity Date shall in any event be in an amount equal to the aggregate principal amount of all Term Loans outstanding on such date.

Section 4.02 Repayment of LC Loans. The Borrower unconditionally and irrevocably promises to pay to the Credit Facility Agent for the ratable account of each Working Capital Lender the aggregate outstanding principal amount of each LC Loan no later than 5:00 p.m. on the Working Capital Loan Termination Date.

Section 4.03 Repayment of Working Capital Advances.

(a) The Borrower shall reduce the aggregate outstanding principal amount of all Working Capital Loans to zero Dollars ($0) for a period of five (5) consecutive Business Days at least once every calendar year; provided that, the Borrower will determine in its sole discretion when during any calendar year it elects to satisfy such requirement and the Credit Facility Agent shall have no duty to monitor compliance with this Section 4.03(a) (Repayment of Working Capital Advances); provided further that the Borrower may not borrow amounts under any other Facility Agreement for Working Capital Debt in order to meet the requirement specified in this Section 4.03(a) (Repayment of Working Capital Advances).

(b) Notwithstanding anything to the contrary set forth in Section 4.03(a) (Repayment of Working Capital Advances), the Borrower unconditionally and irrevocably promises to pay to the Credit Facility Agent for the ratable account of each Working Capital Lender, on the Working Capital Loan Termination Date, an amount equal to the aggregate principal amount of all Working Capital Loans then-outstanding.

Section 4.04 Interest Payment Dates. (a) Interest accrued on each Loan shall be payable, without duplication, on the following dates (each, an “Interest Payment Date”):

(i) with respect to any repayment or prepayment of principal on such Loan, on the date of each such repayment or prepayment;

 

25


(ii) on the Final Maturity Date;

(iii) with respect to Working Capital Loans and LC Loans, the Working Capital Loan Termination Date;

(iv) with respect to SOFR Loans, (A) on the last day of each applicable Interest Period; provided that, in the case of any Interest Period that has a duration of more than three months, the Interest Payment Date in respect of such SOFR Loans shall also include each day that is three months (or an integral multiple thereof) after the first day of such Interest Period, and (B) if applicable, on any date on which such SOFR Loan is converted to a Base Rate Loan; and

(v) with respect to Base Rate Loans, on the last Business Day of each calendar quarter or, if applicable, any date on which such Base Rate Loan is converted to a SOFR Loan.

(b) Interest accrued on the Loans or other monetary Loan Obligations after the date such amount is due and payable (whether on the Final Maturity Date or any CTA Payment Date upon acceleration or otherwise) shall be payable upon demand.

(c) Interest hereunder shall be due and payable in accordance with the terms hereof before and after judgment, and before and after the occurrence of an event set forth in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement and (to the extent Section 9.01 (Events of Default) covers the events described in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement) Section 9.01 (Events of Default) of this Agreement.

Section 4.05 Interest Rates.

(a) Each SOFR Loan shall accrue interest at a rate per annum during each Interest Period applicable thereto equal to the sum of Term SOFR for such Interest Period plus the Applicable Margin for such Loan.

(b) On or before 1:00 p.m. at least three (3) U.S. Government Securities Business Days prior to the end of each Interest Period for each SOFR Loan, the Borrower shall deliver to the Credit Facility Agent an Interest Period Notice setting forth the Borrower’s election with respect to the duration of the next Interest Period applicable to such SOFR Loan, which Interest Period shall be one (1), three (3) or six (6) months in length (or, if available to all applicable Lenders, such other periods as may be agreed by the Credit Facility Agent (including with respect to the Applicable Margin agreed to by all the Lenders with respect to any such Interest Period)); provided that, (i) if any Loan Facility Declared Default has occurred and is Continuing, all SOFR Loans shall convert into Base Rate Loans and (ii) if any Unmatured Loan Facility Event of Default has occurred and is Continuing at the end of the then-current Interest Periods, all SOFR Loans shall convert into SOFR Loans with an Interest Period of one (1) month, in each case, at the end of the then-current Interest Periods (in which case the Credit Facility Agent shall so notify the Borrower and the Lenders). After such Loan Facility Declared Default or Unmatured Loan Facility Event of Default has ceased, the Borrower may convert each such Base Rate Loan or SOFR Loan with an Interest Period of one month into a SOFR Loan in accordance with this Agreement by delivering an Interest Period Notice in accordance with Section 4.06 (Conversion Options).

 

26


(c) If the Borrower fails to deliver an Interest Period Notice in accordance with Section 4.05(b) (Interest Rates) above with respect to any SOFR Loan, such SOFR Loan shall be made as, or converted into, a Base Rate Loan at the end of the then-current Interest Period.

(d) Each SOFR Loan shall bear interest from (and including) the first day of the applicable Interest Period to (but excluding) the last day of such Interest Period (or the date such Loan is converted to a Base Rate Loan) at the interest rate determined as applicable to such SOFR Loan.

(e) Notwithstanding anything to the contrary contained herein, the Borrower shall have, in the aggregate, no more than fifteen (15) separate SOFR Loans outstanding at any one time.

(f) Each Base Rate Loan shall accrue interest at a rate per annum equal to the sum of the Base Rate plus the Applicable Margin for such Loan.

(g) All Base Rate Loans shall bear interest from and including the date such Loan is made (or the day on which SOFR Loans are converted to Base Rate Loans in accordance with Section 4.05(c) (Interest Rates) or 4.06 (Conversion Options) or under Article V (SOFR and Tax Provisions)) to (but excluding) the date such Loan or portion thereof is paid at the interest rate determined as applicable to such Base Rate Loan (or the date such Loan is converted to a SOFR Loan).

(h) In connection with the use or administration of Term SOFR, the Credit Facility Agent will have the right to make Conforming Changes from time to time and, notwithstanding anything to the contrary herein or in any other Finance Document, any amendments implementing such Conforming Changes will become effective without any further action or consent of any other party to this Agreement or any other Finance Document. The Credit Facility Agent will promptly notify the Borrower and the Lenders of the effectiveness of any Conforming Changes in connection with the use or administration of Term SOFR.

Section 4.06 Conversion Options. The Borrower may elect from time to time to convert SOFR Loans to Base Rate Loans or Base Rate Loans to SOFR Loans (subject to Sections 4.05(e) (Interest Rates), 5.01 (Illegality) and 5.02 (Inability to Determine Applicable Interest Rate)), as the case may be, by delivering a completed Interest Period Notice to the Credit Facility Agent notifying the Credit Facility Agent of such election no later than 12:00 noon on the third (3rd) Business Day preceding the proposed conversion date (which notice, in the case of conversions to SOFR Loans, shall specify the length of the initial Interest Period therefor); provided that, (i) no Base Rate Loan may be converted into a SOFR Loan when any Loan Facility Declared Default has occurred and is Continuing and (ii) no Base Rate Loan may be converted into a SOFR Loan with an Interest Period greater than one month when any Unmatured Loan Facility Event of Default has occurred and is Continuing and, in each case, the Credit Facility Agent has determined not to permit such conversions. Upon receipt of any such notice, the Credit Facility Agent shall promptly notify each relevant Lender thereof.

 

27


Section 4.07 Post-Maturity Interest Rates; Default Interest Rates. If all or a portion of the principal amount of any Loan is not paid when due (whether on the Final Maturity Date, by acceleration or otherwise, or in the case of LC Loans, the Working Capital Loan Termination Date or otherwise) or any Loan Obligation (other than principal on the Loans) is not paid or deposited when due (whether on the Final Maturity Date, by acceleration or otherwise), (a) all such overdue amounts of principal on the Loans shall bear interest at a rate per annum equal to the rate that would otherwise be applicable thereto plus the Default Rate and (b) all such other defaulted amounts of Loan Obligations (other than principal on the Loans) shall bear interest at a rate per annum equal to the rate then applicable to Base Rate Loans plus the Default Rate, from the date of such non-payment until the amount then due is paid in full (after as well as before judgment).

Section 4.08 Interest Rate Determination. The Credit Facility Agent shall determine the interest rate applicable to the Loans and shall give prompt notice of such determination to the Borrower and the applicable Lenders. In each such case, the Credit Facility Agent’s determination of the applicable interest rate shall be conclusive, in the absence of manifest error.

Section 4.09 Computation of Interest and Fees.

(a) All computations of interest for Base Rate Loans when the Base Rate is determined by the Credit Facility Agent’s “prime rate” shall be made on the basis of a year of 365 or 366 days, as the case may be, and actual days elapsed. All computations of interest for SOFR Loans, and for Base Rate Loans when the Base Rate is determined by Term SOFR shall be made on the basis of a 360 day year and actual days elapsed. All computations of commissions or fees owed hereunder (other than Commitment Fees, Fronting Fees and LC Fees, which shall be computed in accordance with the provisions of Section 4.15 (Fees) below) shall be made on the basis of a year of 365 or 366 days, as the case may be, and actual days elapsed (including the first day but excluding the last day).

(b) Interest shall accrue on each Loan for the day on which the Loan is made, and shall not accrue on a Loan, or any portion thereof, for the day on which the Loan or such portion is paid; provided, that, any Loan that is repaid on the same day on which it is made shall bear interest for one day.

(c) Each computation by the Credit Facility Agent of interest or fees hereunder shall be conclusive and binding for all purposes, absent manifest error.

Section 4.10 Terms of All Prepayments. The Borrower shall make prepayments of Loans and all reductions and cancellations of Commitments in accordance with the terms of Article 3 (Repayment, Prepayment and Cancellation) of the Common Terms Agreement and subject to the following terms and the terms of Section 4.11 (Voluntary Prepayments) and Section 4.12 (Mandatory Prepayment):

(a) upon the prepayment of any Loans (whether a voluntary prepayment, a mandatory prepayment or a prepayment upon acceleration or otherwise), the Borrower shall satisfy all applicable provisions under this Agreement; and

 

28


(b) together with any prepayment of Loans, the Borrower shall pay to the Credit Facility Agent, for the account of the applicable Lenders which made any Loan being prepaid, the sum of the following amounts:

(i) the principal of, and accrued but unpaid interest on, the Loans to be prepaid;

(ii) any additional amounts required to be paid under Section 5.05 (Funding Losses), which payment shall be made within the time period after the applicable prepayment as is permitted under the Common Terms Agreement; and

(iii) any other Loan Obligations required to be paid to the respective Lenders in connection with any prepayment under the Finance Documents.

Section 4.11 Voluntary Prepayment.

(a) The Borrower may, in accordance with Section 3.5 (Voluntary Prepayments) of the Common Terms Agreement and on not less than three (3) Business Days’ prior written notice to the Credit Facility Agent, prepay in whole or in part amounts outstanding under the Credit Facility Agreement, without penalty or premium (other than any costs incurred as set forth in Section 5.05 (Funding Losses)); provided that, each voluntary prepayment of Loans shall be in incremental multiples of $1,000,000. Such notice may be conditional and subject to revocation as set forth in Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement. If any such notice is revoked in accordance with Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement, the Borrower shall pay any costs incurred by any Lender as a result of such notice and revocation, as set forth in Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement. Prepayments of Working Capital Loans shall not result in any reduction in Working Capital Commitments, except to the extent prepaid in accordance with Sections 4.12(b)(ii), (iii) and (iv) (Mandatory Prepayment).

(b) Except as set forth in Section 3.5(b) (Voluntary Prepayments) of the Common Terms Agreement, after the Borrower has delivered a notice of voluntary prepayment in accordance with Section 4.11(a) (Voluntary Prepayment) above, the prepayment date specified in the notice shall be deemed the due date for the principal amount (and the interest thereon) to be paid thereunder and should the Borrower fail to pay any such principal amount and/or interest and/or prepayment premium (if any), in accordance with Section 3.6 (Prepayment Fees and Funding Losses) of the Common Terms Agreement and Section 5.05 (Funding Losses) due on such date, the Borrower shall pay interest on such overdue amounts in accordance with Section 4.07 (Post-Maturity Interest Rates; Default Interest Rates).

(c) Pursuant to Section 3.7 (Pro Rata Payment) of the Common Terms Agreement and Section 2.3(a)(i)(B) (Payments and Prepayments - Pro Rata Payment of Senior Debt Obligations) of the Common Security and Account Agreement (i) any voluntary prepayment of Working Capital Loans or LC Loans may be made without a voluntary pro rata prepayment of Senior Debt under any other Senior Debt Instrument and (ii) any voluntary prepayment of Senior Debt under any other Senior Debt Instrument may be made without a voluntary pro rata prepayment of Working Capital Loans or LC Loans.

 

29


Section 4.12 Mandatory Prepayment.

(a) The Borrower shall prepay, with three (3) Business Days’ prior written notice to the Credit Facility Agent, the Term Loans as and when required under Section 3.4 (Mandatory Prepayments) and Section 3.7 (Pro Rata Payment) of the Common Terms Agreement.

(b) The Borrower shall prepay, with three (3) Business Days’ prior written notice to the Credit Facility Agent, the Working Capital Loans or LC Loans in accordance with Section 3.4 (Mandatory Prepayments) and Section 3.7 (Pro Rata Payment) of the Common Terms Agreement solely in the following circumstances:

(i) other than LC Loans incurred to fund a reimbursement obligation with respect to a drawing under a Letter of Credit, as needed to comply with Section 4.03(a) (Repayment of Working Capital Advances); provided that, for the avoidance of doubt, the Borrower shall not be required to cause any issued and outstanding Letters of Credit to be cancelled or returned;

(ii) in accordance with Section 3.4(a)(iii) (Mandatory Prepayments – LNG SPA Prepayment Events) of the Common Terms Agreement;

(iii) in accordance with Section 3.4(a)(vi) (Mandatory Prepayments – Illegality) of the Common Terms Agreement as a result of the occurrence of an Illegality Event with respect to a Working Capital Lender; and

(iv) in accordance with Section 3.4(a)(x) (Mandatory Prepayments – Replacement Debt) of the Common Terms Agreement in the event and to the extent the additional debt triggering such prepayment has been incurred to replace such Working Capital Loans and/or LC Loans.

Working Capital Commitments shall be cancelled in the case of the mandatory prepayments set forth in clauses (ii) and (iv) above as provided in Sections 3.4(a)(iii) (Mandatory Prepayments – LNG SPA Prepayment Events) and 3.4(a)(x) (Mandatory Prepayments – Replacement Debt) of the Common Terms Agreement, respectively, and shall be suspended in the case of the mandatory prepayment set forth in clause (iii) above as provided in Section 3.4(a)(vi) (Mandatory Prepayments – Illegality) of the Common Terms Agreement.

(c) Application of Prepayments of Loans to Base Rate Loans and SOFR Loans. Any prepayment of Loans of a Lender pursuant to this Section 4.12 (Mandatory Prepayment) shall be applied first to such Lender’s Base Rate Loans to the full extent thereof and second to such Lender’s SOFR Loans.

Section 4.13 Time and Place of Payments.

(a) Except as provided in Section 3.02(b) (Reimbursement to Issuing Banks), the Borrower shall make each payment (including any payment of principal of or interest on any Loan or any Fees or other Loan Obligations) hereunder without set-off, deduction or counterclaim not later than 12:00 noon New York City time on the date when due in Dollars and, in immediately

 

30


available funds, to the Credit Facility Agent at the account set forth in Schedule IV (Credit Facility Agent Account Details) or at such other office or account as may from time to time be specified by the Credit Facility Agent to the Borrower. Funds received after 12:00 noon New York City time may, at the Credit Facility Agent’s discretion, be deemed to have been received by the Credit Facility Agent on the next succeeding Business Day.

(b) The Credit Facility Agent shall promptly remit in immediately available funds to each Credit Facility Secured Party its share, if any, of any payments received by the Credit Facility Agent for the account of such Credit Facility Secured Party.

(c) Whenever any payment (including any payment of principal of or interest on any Term Loan or any Fees or other Loan Obligations) hereunder shall become due, or otherwise would occur, on a day that is not a Business Day, such payment shall (except as otherwise required by the proviso to the definition of “Interest Period” with respect to SOFR Loans and in the case of the Final Maturity Date, in which case the due date for payment shall be the immediately preceding Business Day) be made on the immediately succeeding Business Day, and such increase of time shall in such case be included in the computation of interest or Fees, if applicable.

Section 4.14 Advances and Payments Generally.

(a) Except as provided in Section 3.02(b) (Reimbursement to Issuing Banks), unless the Credit Facility Agent has received notice from the Borrower prior to the date on which any payment is due to the Credit Facility Agent for the account of the Lenders or any Issuing Bank hereunder that the Borrower will not make such payment, the Credit Facility Agent may assume that the Borrower has made such payment on such date in accordance with this Agreement and may, in reliance upon such assumption, distribute to the Lenders or the applicable Issuing Bank(s) the amount due. If the Borrower has not in fact made such payment, then each of the Lenders or the applicable Issuing Bank(s) severally agrees to repay to the Credit Facility Agent forthwith on demand the amount so distributed to such Lender in immediately available funds with interest thereon, for each day from (and including) the date such amount is distributed to it to (but excluding) the date of payment to the Credit Facility Agent, at the Federal Funds Effective Rate. A notice of the Credit Facility Agent to any Lender or Issuing Bank with respect to any amount owing under this Section 4.14 (Advances and Payments Generally) shall be conclusive, absent manifest error.

(b) Nothing herein shall be deemed to obligate any Lender or Issuing Bank to obtain funds for any Loan or Letter of Credit reimbursement obligation in any particular place or manner or to constitute a representation by any Lender or Issuing Bank that it has obtained or will obtain funds for any Loan in any particular place or manner.

Section 4.15 Fees.

(a) From and including the Initial Closing Date until the end of the Term Loan Availability Period or with respect to any Term Lender, until the date on which such Term Lender’s Term Loan Commitments are terminated (solely to the extent of such terminated Term Loan Commitments), the Borrower agrees to pay to the Credit Facility Agent, for the account of the Term Lenders, on each CTA Payment Date beginning on the first CTA Payment Date that is

 

31


also an Interest Payment Date and on the last day of the Term Loan Availability Period, a commitment fee (a “Term Loan Commitment Fee”) on the daily average amount by which the Term Loan Commitments exceed the aggregate outstanding principal amount of the Term Loans during the relevant fiscal quarter (or portion thereof) then ended at a rate per annum equal to the Commitment Fee Rate. Notwithstanding the foregoing, the Borrower will not be required to pay any Term Loan Commitment Fee to any Term Lender with respect to any period in which such Term Lender was a Defaulting Lender.

(b) From and including the Initial Closing Date until the Working Capital Loan Termination Date, the Borrower agrees to pay to the Credit Facility Agent, for the account of each Working Capital Lender, on each CTA Payment Date beginning on the first CTA Payment Date that is also an Interest Payment Date and on the Working Capital Loan Termination Date, a commitment fee (a “Working Capital Commitment Fee” and, together with the Term Loan Commitment Fee, the “Commitment Fees”) on the daily average amount of such Working Capital Lender’s unused Working Capital Commitment at a rate per annum equal to the Commitment Fee Rate. Notwithstanding the foregoing, the Borrower will not be required to pay any Working Capital Commitment Fee to any Working Capital Lender with respect to any period in which such Working Capital Lender was a Defaulting Lender.

(c) The Borrower agrees to pay to the Credit Facility Agent for the account of each Working Capital Lender, on each CTA Payment Date beginning on the first CTA Payment Date that is also an Interest Payment Date commencing on the first such date to occur following the date of issuance of any Letter of Credit hereunder, and on the Working Capital Loan Termination Date, a letter of credit fee (the “LC Fee”) on (i) the average daily aggregate amount of such Working Capital Lender’s Commitment Percentage of the LC Available Amount, if any, of all Fronted Letters of Credit, and (ii) the average daily aggregate amount of the LC Available Amount, if any, of any Non-Fronted Letters of Credit issued by such Working Capital Lender in its capacity as an Issuing Bank, each at a rate per annum equal to the LC Fee Rate; provided that, upon the occurrence and during the continuance of a Loan Facility Event of Default, with respect to any outstanding Letters of Credit which are not cash collateralized pursuant to Section 9.05 (Application of Proceeds), such LC Fee shall be increased by 2.0% per annum.

(d) The Borrower agrees to pay to each Issuing Bank, on each CTA Payment Date beginning on the first CTA Payment Date that is also an Interest Payment Date commencing on the first such date to occur following the date of issuance of such Letter of Credit hereunder, and on the Working Capital Loan Termination Date, a letter of credit fronting fee (the “Fronting Fee”) in an amount equal to 0.20% per annum of the aggregate LC Available Amount of each Fronted Letter of Credit issued by such Issuing Bank.

(e) The Borrower agrees to pay or cause to be paid to the Credit Facility Agent for the account of the Lenders and the Credit Facility Agent, additional fees in the amounts and at the times from time to time agreed to by the Borrower and the Credit Facility Agent, including pursuant to each fee letter with an Initial Coordinating Lead Arranger or Initial Documentation Bank, an Upsize Coordinating Lead Arranger or Upsize Documentation Bank and any other fee letters entered into by the Borrower with any of the Lenders from time to time in respect of the Credit Facility Agreement.

 

32


(f) All Fees shall be paid on the dates due in immediately available funds. Once paid, none of the Fees shall be refundable under any circumstances.

(g) All Commitment Fees, Fronting Fees and LC Fees shall be computed on the basis of 360-day year, as prorated for any partial quarter, as applicable.

(h) The Borrower shall not be liable to pay any Lender or Issuing Bank any upfront fees, fronting fees or agent fees, nor shall it be liable to pay any other fees, costs, expenses or charges with respect to the transactions contemplated under this Agreement, other than as may be specifically stated in this Agreement, the Fee Letters or any other agreement in writing between such Lender or Issuing Bank and the Borrower.

Section 4.16 Pro Rata Treatment.

(a) The portion of any Type of Loan or Advance made shall be allocated by the Credit Facility Agent among the applicable Lenders such that, following each Loan or Advance, the ratio of each Lender’s outstanding Commitments of such Type to the outstanding Aggregate Commitment of such Type is equal to each Lender’s respective Commitment Percentage of such Type.

(b) Except as otherwise provided in Section 5.01 (Illegality), each reduction of Commitments of any Type, pursuant to Section 2.07 (Termination or Reduction of Commitments) or otherwise, shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with, and subject to the exceptions in, Section 2.07 (Termination or Reduction of Commitments) and Section 3.8 (Reductions and Cancellations of Facility Debt Commitments) of the Common Terms Agreement. Each reduction in Issuing Bank Limits shall be allocated by the Credit Facility Agent pro rata among the Issuing Banks.

(c) Except as otherwise required under Section 3.7 (Pro Rata Payment) of the Common Terms Agreement and Section 4.11 (Voluntary Prepayment), Section 4.12 (Mandatory Prepayment) or Article V (SOFR and Tax Provisions), (i) each payment or prepayment of principal of a Type of Loans shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with the respective principal amounts of their outstanding Loans of such Type (other than Defaulting Lenders) without regard to whether such Term Loans or Term Loan Commitments are with respect to any Initial Term Loan Commitments or Incremental Term Loan Commitments, (ii) each payment of interest on a Type of Loans shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with the respective interest amounts outstanding on their Loans of such Type (other than Defaulting Lenders) and (iii) each payment of the Commitment Fees shall be allocated by the Credit Facility Agent pro rata among the applicable Lenders in accordance with their respective Term Loan Commitments or Working Capital Commitments (other than Defaulting Lenders), as applicable.

 

33


Section 4.17 Sharing of Payments.

(a) If any Lender or Issuing Bank obtains any payment or other recovery (whether voluntary, involuntary, by application of setoff or otherwise) on account of any Type of Loan (other than pursuant to the terms of Article V (SOFR and Tax Provisions) or Section 4.16 (Pro Rata Treatment)) in excess of its pro rata share of payments then or therewith obtained by all Lenders holding Loans of such Type, such Lender or Issuing Bank shall purchase from the other applicable Lenders (for cash at face value) such participations in Loans of such Type made by them as shall be necessary to cause such purchasing Lender to share the excess payment or other recovery ratably with each of them; provided that, if all or any portion of the excess payment or other recovery is thereafter recovered from such purchasing Lender or Issuing Bank, the purchase shall be rescinded and each Lender that has sold a participation to the purchasing Lender or Issuing Bank shall repay to the purchasing Lender or Issuing Bank the purchase price to the ratable extent of such recovery together with an amount equal to such selling Lender’s ratable share (according to the proportion of (i) the amount of such selling Lender’s required repayment to the purchasing Lender or Issuing Bank to (ii) the total amount so recovered from the purchasing Lender or Issuing Bank) of any interest or other amount paid or payable by the purchasing Lender or Issuing Bank in respect of the total amount so recovered. The Borrower agrees that any Lender or Issuing Bank so purchasing a participation from another Lender pursuant to this Section 4.17(a) (Sharing of Payments) may, to the fullest extent permitted by law, exercise all its rights of payment (including pursuant to Section 11.13 (Right of Set-Off)) with respect to such participation as fully as if such Lender or Issuing Bank were the direct creditor of the Borrower in the amount of such participation. The provisions of this Section 4.17 (Sharing of Payments) shall not be construed to apply to any payment by the Borrower pursuant to and in accordance with the express terms of this Agreement or any payment obtained by any Lender as consideration for the assignment or sale of a participation in any of its Loans.

(b) If under any applicable bankruptcy, insolvency or other similar law, any Lender receives a secured claim in lieu of a setoff to which this Section 4.17 (Sharing of Payments) applies, such Lender shall, to the extent practicable, exercise its rights in respect of such secured claim in a manner consistent with the rights of the Lenders entitled under this Section 4.17 (Sharing of Payments) to share in the benefits of any recovery on such secured claim.

Section 4.18 Defaulting Lenders.

(a) Notwithstanding anything to the contrary contained in this Agreement, if any Lender becomes a Defaulting Lender, then, until such time as such Lender is no longer a Defaulting Lender, to the extent permitted by applicable law, any payment of principal, interest, fees or other amounts received by the Credit Facility Agent for the account of such Defaulting Lender (whether voluntary or mandatory, at maturity, pursuant to Article IX (Default and Enforcement) or otherwise) shall be applied at such time or times as may be determined by the Credit Facility Agent as follows: first, to the payment of any amounts owing by such Defaulting Lender to the Credit Facility Agent hereunder or under any other Finance Document; second, to the payment on a pro rata basis of any amounts owing by such Defaulting Lender to any Issuing Bank hereunder; third, to cash collateralize the Issuing Banks’ Fronting Exposure, if any, with respect to such Defaulting Lender in accordance with the procedures set forth in Section 9.03(a) (Action Upon Event of Default); fourth, as the Borrower may request (so long as no Loan Facility Event of Default or Unmatured Loan Facility Event of Default exists), to the funding of any Advance or Loan in respect of which such Defaulting Lender has failed to fund its portion thereof as required by this Agreement, as determined by the Credit Facility Agent; fifth, if so determined by the Credit Facility Agent and the Borrower, to be held in a deposit account and released pro rata in order to (i) satisfy

 

34


such Defaulting Lender’s potential future funding obligations with respect to Advances or Loans under this Agreement and (ii) cash collateralize the Issuing Banks’ future Fronting Exposure, if any, with respect to such Defaulting Lender with respect to future Letters of Credit issued under this Agreement in accordance with the procedures set forth in Section 9.03(a) (Action Upon Event of Default); sixth, to the payment of any amounts owing to the Lenders or the Issuing Banks as a result of any judgment of a court of competent jurisdiction obtained by any Lender or any Issuing Bank against such Defaulting Lender as a result of such Defaulting Lender’s breach of its obligations under this Agreement; seventh, so long as no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is continuing, to the payment of any amounts owing to the Borrower as a result of any judgment of a court of competent jurisdiction obtained by the Borrower against such Defaulting Lender as a result of such Defaulting Lender’s breach of its obligations under this Agreement; and eighth, to such Defaulting Lender or as otherwise directed by a court of competent jurisdiction; provided that, if (A) such payment is a payment of the principal amount of any Loans in respect of which such Defaulting Lender has not fully funded its appropriate share, and (B) such Loans were made or the related Letters of Credit were issued at a time when the conditions set forth in Section 7.01 (Conditions to Initial Closing), Section 7.02 (Conditions to Upsize Closing), Section 7.03 (Conditions to Each Term Loan Advance) or Section 7.04 (Conditions to Each Working Capital Advance), as applicable, were satisfied or waived, such payment shall be applied solely to pay the Loans owed to all Non- Defaulting Lenders on a pro rata basis, without regard to whether such Term Loans or Term Loan Commitments are with respect to any Initial Term Loan Commitments or Incremental Term Loan Commitments, prior to being applied to the payment of any Loans owed to such Defaulting Lender until such time as all Loans and funded and unfunded participations in Letters of Credit are held by the Lenders pro rata in accordance with their applicable Commitments without giving effect to Section 4.18(b) (Defaulting Lenders). Any payments, prepayments or other amounts paid or payable to a Defaulting Lender that are applied (or held) to pay amounts owed by a Defaulting Lender or to post cash collateral pursuant to this Section 4.18 (Defaulting Lenders) shall be deemed paid to and redirected by such Defaulting Lender, and such Defaulting Lender irrevocably consents hereto.

(b) All or any part of such Defaulting Lender’s participation in LC Exposure shall be reallocated pro rata among the Non-Defaulting Lenders in accordance with their respective Commitment Percentages (calculated without regard to such Defaulting Lender’s Working Capital Commitment) but only to the extent that (i) the conditions set forth in Section 4.4(c) (Conditions to Each Advance under the Working Capital Facility – Absence of Default) and Section 4.4(d) (Conditions to Each Advance under the Working Capital Facility – Representations and Warranties) of the Common Terms Agreement are satisfied at the time of such reallocation, and (ii) such reallocation does not cause the sum of the outstanding principal amount of the Working Capital Loans, LC Loans and the LC Exposure of any Non-Defaulting Lender to exceed such Non- Defaulting Lender’s Working Capital Commitment. No reallocation hereunder shall constitute a waiver or release of any claim of any party hereunder against a Defaulting Lender arising from that Lender having become a Defaulting Lender, including any claim of a Non-Defaulting Lender as a result of such Non-Defaulting Lender’s increased exposure following such reallocation. If the reallocation described in this Section 4.18(b) (Defaulting Lenders) cannot, or can only partially, be effected, the Borrower shall, without prejudice to any right or remedy available to it hereunder or under law, cash collateralize the Issuing Banks’ Fronting Exposure on account of such

 

35


Defaulting Lender (after giving effect to partial reallocations) in accordance with the procedures set forth in Section 9.03(a) (Action Upon Event of Default); provided that, the Borrower shall have sixty (60) days from receipt of written notice by the Credit Facility Agent that the reallocation described in this Section 4.18(b) (Defaulting Lenders) cannot, or can only partially, be effected, to cash collateralize the Issuing Banks’ Fronting Exposure in accordance with this Section 4.18(b) (Defaulting Lenders), so long as no Loan Facility Event of Default shall have occurred and be continuing during such period.

(c) If the Borrower, the Credit Facility Agent and the Issuing Banks agree in writing that a Lender is no longer a Defaulting Lender, the Credit Facility Agent will so notify the parties hereto, whereupon as of the effective date specified in such notice and subject to any conditions set forth therein (which may include arrangements with respect to any cash collateral), that Lender will, to the extent applicable, purchase at par that portion of outstanding Loans of the other Lenders or take such other actions as the Credit Facility Agent may determine to be necessary to cause the Loans and funded and unfunded participations in Letters of Credit to be held pro rata by the Lenders in accordance with the relative amounts of their applicable Commitments (without giving effect to Section 4.18(b) (Defaulting Lenders)), whereupon such Lender will cease to be a Defaulting Lender; provided that, no adjustments will be made retroactively with respect to fees accrued or payments made by or on behalf of the Borrower while that Lender was a Defaulting Lender; and provided further that, except to the extent otherwise expressly agreed by the affected parties, no change hereunder from Defaulting Lender to Non-Defaulting Lender will constitute a waiver or release of any claim of any party hereunder arising from that Lender’s having been a Defaulting Lender.

(d) So long as any Lender is a Defaulting Lender, no Issuing Bank shall be required to issue, amend, extend, renew or increase any Letter of Credit to the extent the reallocation described in Section 4.18(b) (Defaulting Lenders) cannot be effected or the Borrower has not cash collateralized such Issuing Bank’s Fronting Exposure with respect to such Defaulting Lender.

ARTICLE V

SOFR AND TAX PROVISIONS

Section 5.01 Illegality. If any Lender determines that any applicable law has made it unlawful, or that any Governmental Authority has asserted that it is unlawful, for any Lender or its applicable lending office to make, maintain or fund Loans whose interest is determined by reference to SOFR, the Term SOFR Reference Rate or Term SOFR, or to determine or charge interest based upon SOFR, the Term SOFR Reference Rate or Term SOFR, then, upon notice thereof by such Lender to the Borrower (through the Credit Facility Agent) (an “Illegality Notice”), (a) any obligation of the Lenders to make SOFR Loans, and any right of the Borrower to continue SOFR Loans or to convert Base Rate Loans to SOFR Loans, shall be suspended, and (b) the interest rate on which Base Rate Loans shall, if necessary to avoid such illegality, be determined by the Credit Facility Agent without reference to clause (c) of the definition of “Base Rate,” in each case, until each affected Lender notifies the Credit Facility Agent and the Borrower that the circumstances giving rise to such determination no longer exist. Upon receipt of an Illegality Notice, the Borrower shall, if necessary to avoid such illegality, upon demand from any Lender

 

36


(with a copy to the Credit Facility Agent), prepay or, if applicable, convert all SOFR Loans to Base Rate Loans (the interest rate on which Base Rate Loans shall, if necessary to avoid such illegality, be determined by the Credit Facility Agent without reference to clause (c) of the definition of “Base Rate”), on the last day of the Interest Period therefor, if all affected Lenders may lawfully continue to maintain such SOFR Loans to such day, or immediately, if any Lender may not lawfully continue to maintain such SOFR Loans to such day, in each case until the Credit Facility Agent is advised in writing by each affected Lender that it is no longer illegal for such Lender to determine or charge interest rates based upon SOFR, the Term SOFR Reference Rate or Term SOFR. Upon any such prepayment or conversion, the Borrower shall also pay accrued interest on the amount so prepaid or converted, together with any additional amounts required pursuant to Section 5.05 (Funding Losses).

Section 5.02 Inability to Determine Applicable Interest Rate. Subject to Section 5.07 (Replacement Benchmark Setting), if, on or prior to the first day of any Interest Period for any SOFR Loan:

(a) the Credit Facility Agent determines (which determination shall be conclusive and binding absent manifest error) that “Term SOFR” cannot be determined pursuant to the definition thereof, or

(b) the Required Lenders determine that for any reason in connection with any request for a SOFR Loan or a conversion thereto or a continuation thereof that Term SOFR for any requested Interest Period with respect to a proposed SOFR Loan does not adequately and fairly reflect the cost to such Lenders of making and maintaining such SOFR Loan, and the Required Lenders have provided notice of such determination to the Credit Facility Agent,

the Credit Facility Agent will promptly so notify the Borrower and each Lender.

Upon notice thereof by the Credit Facility Agent to the Borrower, any obligation of the Lenders to make SOFR Loans, and any right of the Borrower to continue SOFR Loans or to convert Base Rate Loans to SOFR Loans, shall be suspended (to the extent of the affected SOFR Loans or affected Interest Periods) until the Credit Facility Agent (with respect to clause (b) above, at the instruction of the Required Lenders) revokes such notice. Upon receipt of such notice, (i) the Borrower may revoke any pending request for a borrowing of, conversion to or continuation of SOFR Loans (to the extent of the affected SOFR Loans or affected Interest Periods) or, failing that, the Borrower will be deemed to have converted any such request into a request for a borrowing of or conversion to Base Rate Loans in the amount specified therein and (ii) any outstanding affected SOFR Loans will be deemed to have been converted into Base Rate Loans at the end of the applicable Interest Period. Upon any such conversion, the Borrower shall also pay accrued interest on the amount so converted, together with any additional amounts required pursuant to Section 5.05 (Funding Losses). Subject to Section 5.07 (Replacement Benchmark Setting), if the Credit Facility Agent determines (which determination shall be conclusive and binding absent manifest error) that “Term SOFR” cannot be determined pursuant to the definition thereof on any given day, the interest rate on Base Rate Loans shall be determined by the Credit Facility Agent without reference to clause (c) of the definition of “Base Rate” until the Credit Facility Agent revokes such determination.

 

37


Section 5.03 Increased Costs.

(a) If any Lender or Issuing Bank incurs additional costs or suffers a reduction, in each case, as described in Section 22.1(a) (Increased Costs) of the Common Terms Agreement, the Borrower shall compensate such Lender or Issuing Bank in accordance with Section 22.1(a) (Increased Costs) of the Common Terms Agreement (except to the extent the Borrower is excused from payment pursuant to Section 5.04 (Obligation to Mitigate)). In determining the amount of such compensation, such Lender or Issuing Bank may, subject to Section 22.1(e) (Increased Costs) of the Common Terms Agreement, use any method of averaging and attribution that it (in its sole discretion) shall deem appropriate.

(b) If any Lender or Issuing Bank or Lender’s or Issuing Bank’s holding company has suffered or would suffer a reduced rate of return as described in Section 22.1(b) (Increased Costs) of the Common Terms Agreement, the Borrower shall compensate such Lender or Issuing Bank or (without duplication) such Lender’s or Issuing Bank’s holding company in accordance with Section 22.1(b) (Increased Costs) of the Common Terms Agreement (except to the extent the Borrower is excused from payment pursuant to Section 5.04 (Obligation to Mitigate)).

(c) To claim any amount under this Section 5.03 (Increased Costs), the Credit Facility Agent or a Lender or Issuing Bank, as applicable, shall promptly deliver a certificate in accordance with Section 22.1(c) (Increased Costs) of the Common Terms Agreement (with a copy to the Credit Facility Agent, if delivered by a Lender or Issuing Bank). The Borrower shall pay the Credit Facility Agent or Lender or Issuing Bank, as applicable, in accordance with Section 22.1(c) (Increased Costs) of the Common Terms Agreement.

(d) Promptly after the Credit Facility Agent or Lender or Issuing Bank, as applicable, has determined that it will make a request for increased compensation pursuant to this Section 5.03 (Increased Costs), such Person shall notify the Borrower thereof (with a copy to the Credit Facility Agent and the Intercreditor Agent). Failure or delay on the part of the Credit Facility Agent or Lender or Issuing Bank to demand compensation pursuant to this Section 5.03 (Increased Costs) shall not constitute a waiver of such Person’s right to demand such compensation; provided that, the Borrower shall not be required to compensate a Person pursuant to this Section 5.03 (Increased Costs) for any increased costs or reductions outside of the period referred to in Section 22.1(d) (Increased Costs) of the Common Terms Agreement.

(e) Notwithstanding any other provision in this Agreement, no Lender or Issuing Bank shall demand compensation pursuant to this Section 5.03 (Increased Costs) in the circumstances described in Section 22.1(e) (Increased Costs) of the Common Terms Agreement.

Section 5.04 Obligation to Mitigate.

(a) If any Lender or Issuing Bank requests compensation under Section 5.03 (Increased Costs), or if the Borrower is required to pay any additional amount to any Lender or Issuing Bank or any Governmental Authority for the account of any Lender or Issuing Bank pursuant to Section 5.06 (Taxes), then such Lender or Issuing Bank shall have an obligation to mitigate such compensation in accordance with Section 19.5(a) (Mitigation Obligations; Replacement of Lenders) of the Common Terms Agreement.

 

38


(b) The Borrower may require a Lender or Issuing Bank to assign and delegate (in accordance with and subject to the restrictions contained in Section 11.04 (Assignments)) its interests, rights and obligations under this Agreement and the related Finance Documents in accordance with Section 19.5(c) (Mitigation Obligations; Replacement of Lenders) of the Common Terms Agreement. Nothing in this Section 5.04 (Obligation to Mitigate) shall be deemed to prejudice any rights that the Borrower, the Credit Facility Agent or any Lender or any Issuing Bank may have against any Lender or Issuing Bank that is a Defaulting Lender. Notwithstanding anything in this Section 5.04 (Obligation to Mitigate) to the contrary, any Working Capital Lender that acts as an Issuing Bank may not be replaced hereunder at any time it has any Letter of Credit outstanding hereunder unless arrangements satisfactory to such Working Capital Lender (including the furnishing of a backstop standby letter of credit in form and substance, and issued by an issuer, reasonably satisfactory to such Issuing Bank and/or the depositing of cash collateral into a cash collateral account in amounts and pursuant to arrangements reasonably satisfactory to such Issuing Bank) have been made with respect to such outstanding Letter of Credit.

Section 5.05 Funding Losses. The Borrower shall compensate each Lender, upon written request by such Lender (which request shall set forth the basis for requesting such amounts in reasonable detail), for all reasonable losses, expenses and liabilities (including any interest paid or payable by such Lender to Lenders of funds borrowed by it to make or carry its SOFR Loans and any loss, expense or liability sustained by such Lender in connection with the liquidation or re- employment of such funds but excluding loss of anticipated profits) which such Lender may sustain: (a) if for any reason (other than a default by such Lender) a borrowing of any SOFR Loan does not occur on a date specified therefor in a Disbursement Request or other written request for borrowing, or a conversion to or continuation of any SOFR Loan does not occur on a date specified therefor in an Interest Period Notice or a written request for conversion or continuation; (b) if any prepayment or other principal payment of, or any conversion of, any of its SOFR Loans occurs on a date prior to the last day of an Interest Period applicable to that Loan; (c) if any prepayment of any of its SOFR Loans is not made on any date specified in a notice of prepayment given by the Borrower; or (d) if any SOFR Loan is converted other than on the last day of the Interest Period applicable thereto (including as a result of a Loan Facility Event of Default).

Section 5.06 Taxes. Any and all payments on account of any Loan Obligations shall be made in accordance with the provisions of Article 21 (Tax Gross-up and Indemnities) of the Common Terms Agreement.

Section 5.07 Replacement Benchmark Setting.

(a) Benchmark Replacement.

(i) Notwithstanding anything to the contrary herein or in any other Finance Document, upon the occurrence of a Benchmark Transition Event, the Credit Facility Agent and the Borrower may amend this Agreement to replace the then-current Benchmark with a Benchmark Replacement. Any such amendment with respect to a Benchmark Transition Event will become effective at 5:00 p.m. (New York City time) on the fifth (5th) Business Day after the Credit Facility Agent has posted such proposed amendment to all affected Lenders and the Borrower so long as the Credit Facility Agent has not received,

 

39


by such time, written notice of objection to such amendment from Lenders comprising the Required Lenders. No replacement of a Benchmark with a Benchmark Replacement pursuant to this Section 5.07(a)(i) (Benchmark Replacement) will occur prior to the applicable Benchmark Transition Start Date.

(ii) No Interest Rate Hedging Instrument shall be deemed to be a “Finance Document” for purposes of this Section 5.07(a)(ii) (Benchmark Replacement).

(b) Benchmark Replacement Conforming Changes. In connection with the use, administration, adoption or implementation of a Benchmark Replacement, the Credit Facility Agent will have the right to make Conforming Changes from time to time and, notwithstanding anything to the contrary herein or in any other Finance Document, any amendments implementing such Conforming Changes will become effective without any further action or consent of any other party to this Agreement or any other Finance Document.

(c) Notices; Standards for Decisions and Determinations. The Credit Facility Agent will promptly notify the Borrower and the Lenders of (i) the implementation of any Benchmark Replacement and (ii) the effectiveness of any Conforming Changes in connection with the use, administration, adoption or implementation of a Benchmark Replacement. The Credit Facility Agent will promptly notify the Borrower of (A) the removal or reinstatement of any tenor of a Benchmark pursuant to Section 5.07(d) (Unavailability of Tenor of Benchmark) and (B) the commencement of any Benchmark Unavailability Period. Any determination, decision or election that may be made by the Credit Facility Agent or, if applicable, any Lender (or group of Lenders) pursuant to this Section 5.07 (Replacement Benchmark Setting), including any determination with respect to a tenor, rate or adjustment or of the occurrence or non-occurrence of an event, circumstance or date and any decision to take or refrain from taking any action or any selection, will be conclusive and binding absent manifest error and may be made in its or their sole discretion and without consent from any other party to this Agreement or any other Finance Document, except, in each case, as expressly required pursuant to this Section 5.07 (Replacement Benchmark Setting).

(d) Unavailability of Tenor of Benchmark. Notwithstanding anything to the contrary herein or in any other Finance Document, at any time (including in connection with the implementation of a Benchmark Replacement), (i) if the then-current Benchmark is a term rate (including the Term SOFR Reference Rate) and either (A) any tenor for such Benchmark is not displayed on a screen or other information service that publishes such rate from time to time as selected by the Credit Facility Agent in its reasonable discretion or (B) the administrator of such Benchmark or the regulatory supervisor for the administrator of such Benchmark has provided a public statement or publication of information announcing that any tenor for such Benchmark is not or will not be representative or in compliance with or aligned with the International Organization of Securities Commissions (IOSCO) Principles for Financial Benchmarks, then the Credit Facility Agent may modify the definition of Interest Period (or any similar or analogous definition) for any Benchmark settings at or after such time to remove such unavailable, non- representative, non-compliant or non-aligned tenor and (ii) if a tenor that was removed pursuant to clause (i) above either (A) is subsequently displayed on a screen or information service for a Benchmark (including a Benchmark Replacement) or (B) is not, or is no longer, subject to an

 

40


announcement that it is not or will not be representative or in compliance with or aligned with the International Organization of Securities Commissions (IOSCO) Principles for Financial Benchmarks for a Benchmark (including a Benchmark Replacement), then the Credit Facility Agent may modify the definition of “Interest Period” (or any similar or analogous definition) for all Benchmark settings at or after such time to reinstate such previously removed tenor.

(e) Benchmark Unavailability Period. Upon the Borrower’s receipt of notice of the commencement of a Benchmark Unavailability Period, the Borrower may revoke any pending request for a SOFR borrowing of, conversion to or continuation of SOFR Loans to be made, converted or continued during any Benchmark Unavailability Period and, failing that, the Borrower will be deemed to have converted any such request into a request for a borrowing of or conversion to Base Rate Loans. During a Benchmark Unavailability Period or at any time that a tenor for the then-current Benchmark is not an Available Tenor, the component of the Base Rate based upon the then-current Benchmark or such tenor for such Benchmark, as applicable, will not be used in any determination of the Base Rate.

(f) Tax Matters. The Credit Facility Agent will use commercially reasonable efforts to cooperate with the Borrower to effectuate the terms of this Section 5.07 (Replacement Benchmark Setting) and any resulting modification of the terms with the goal of avoiding a deemed exchange under Section 1001 of the Code.

ARTICLE VI

REPRESENTATIONS AND WARRANTIES

Section 6.01 Incorporation of Common Terms Agreement. The representations and warranties of the Obligors set forth in Article 5 (Representations and Warranties of the Obligors) of the Common Terms Agreement have been made to and for the benefit of each of the Lenders and shall apply mutatis mutandis to this Article VI as if fully set forth herein.

ARTICLE VII

CONDITIONS PRECEDENT

Section 7.01 Conditions to Initial Closing. The occurrence of the Initial Closing, the effectiveness of the Initial Lenders’ Initial Commitments, the obligation of each of the Initial Lenders to make available its Initial Advance and the obligation of the Initial Issuing Banks to issue any Letters of Credit on the Initial Closing Date shall be subject to the satisfaction (or waiver by each of the Initial Lenders and each of the Initial Issuing Banks) of each of the conditions precedent set forth in Section 4.1 (Conditions to Initial Closing Date and Initial Advance) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.01 (Conditions to Initial Closing) as if fully set forth herein.

 

41


Section 7.02 Conditions to Upsize Closing. The occurrence of the Upsize Closing, the effectiveness of the Incremental Lenders’ Incremental Commitments, and the obligation of the Incremental Issuing Banks to issue any Letters of Credit on the Upsize Closing Date shall be subject to the satisfaction (or waiver by each of the Lenders and each of the Issuing Banks) of each of the conditions precedent set forth in Section 4.2 (Conditions to Upsize Closing Date) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.02 (Conditions to Upsize Closing) as if fully set forth herein.

Section 7.03 Conditions to Each Term Loan Advance. The obligation of each Term Lender to make any Advance of Term Loans (whether from the Base Term Loan Commitment or Contingency Reserve Term Loan Commitment) shall be subject to the satisfaction (or waiver by the Credit Facility Agent acting on the instruction of the Required Term Lenders), prior to the making of such Advance, of each of the conditions precedent (and in the case of any Advance of Term Loans other than the Initial Advance, no others) set forth in Section 4.3 (Conditions to Each Term Loan Advance) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.03 (Conditions to Each Term Loan Advance) as if fully set forth herein.

Section 7.04 Conditions to Each Working Capital Advance.

The obligation of (i) any Issuing Bank to issue Letters of Credit (or extend the maturity thereof (other than any automatic extension thereunder) or modify or amend the terms thereof) and (ii) the Working Capital Lenders to make available Working Capital Loans, in each case, subsequent to the Initial Closing Date is subject to the satisfaction (or waiver by the Credit Facility Agent acting on the instruction of the Required Working Capital Lenders and the relevant Issuing Banks, as applicable), prior to issuing such Letter of Credit (or extension, modification or amendment thereof) or to the making of such Working Capital Advance, of each of the conditions precedent set forth in Section 4.4 (Conditions to Each Advance under the Working Capital Facility) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.04 (Conditions to Each Working Capital Advance) as if fully set forth herein.

Section 7.05 Conditions to Occurrence of the Project Phase 1 Completion Date.

The occurrence of the Project Phase 1 Completion Date is subject to the satisfaction of each of the conditions (or waiver by the Credit Facility Agent acting on the instruction of the Required Lenders) of the conditions precedent set forth in Section 14.1 (Conditions to Occurrence of the Project Phase 1 Completion Date) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.05 (Conditions to Occurrence of the Project Phase 1 Completion Date) as if fully set forth herein.

Section 7.06 Conditions to Occurrence of the Project Phase 2 Completion Date.

The occurrence of the Project Phase 2 Completion Date is subject to the satisfaction of each of the conditions (or waiver by the Credit Facility Agent acting on the instruction of the Required Lenders) of the conditions precedent set forth in Section 14.3 (Conditions to Occurrence of the Project Phase 2 Completion Date) of the Common Terms Agreement, which conditions precedent are incorporated by reference and shall apply mutatis mutandis to this Section 7.06 (Conditions to Occurrence of the Project Phase 2 Completion Date) as if fully set forth herein.

 

42


ARTICLE VIII

COVENANTS

Section 8.01 Covenants. The covenants of the Obligors set forth in Article 6 (Incurrence of Additional Senior Debt), Article 7 (Permitted Development Expenditures/Expansions), Article 8 (LNG SPA Covenants), Article 9 (Material Construction Contracts), Article 10 (Reporting by the Borrower), Article 11 (Restricted Payments), Article 12 (Obligor Covenants), Article 13 (Consultants), Section 14.2 (Project Phase 1 Completion Date Transfers), Section 14.4 (Project Phase 2 Completion Date Waterfall) and Article 20 (Subordination) of the Common Terms Agreement have been made to and for the benefit of each of the Lenders and shall apply mutatis mutandis to this Article VIII as if fully set forth herein.

ARTICLE IX

DEFAULT AND ENFORCEMENT

Section 9.01 Events of Default. The occurrence of any Loan Facility Event of Default under the Common Terms Agreement shall constitute an event of default under this Agreement, subject to all of the relevant provisions of the Common Terms Agreement.

Section 9.02 Acceleration Upon Bankruptcy. If any Loan Facility Event of Default described in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement occurs, all outstanding Commitments, if any, shall automatically terminate and the outstanding principal amount of the outstanding Loans and all other Loan Obligations shall automatically be and become immediately due and payable, in each case without notice, demand or further act of the Credit Facility Agent, the Lenders, the Intercreditor Agent, the Collateral Agent or any other Credit Facility Secured Party in accordance with Section 16.1(b) (Facility Lender Remedies for Loan Facility Declared Events of Default - Initiating Percentage for Enforcement Action with Respect to Collateral) of the Common Terms Agreement.

Section 9.03 Action Upon Event of Default.

(a) If any Loan Facility Event of Default under the Common Terms Agreement or this Agreement occurs and is Continuing, the Lenders and the Issuing Banks may, by decision of the Required Lenders (i) instruct the Credit Facility Agent, as Senior Creditor Group Representative for the Lenders and the Issuing Banks, to further instruct the Intercreditor Agent to declare that a Loan Facility Declared Default has occurred under this Agreement in accordance with Section 15.2(a) (Declaration of Loan Facility Declared Default) of the Common Terms Agreement and (ii) thereafter, subject to the Intercreditor Agreement and the Common Security and Account Agreement, exercise, or instruct the Intercreditor Agent to exercise, any Enforcement Action provided under Section 16.1 (Facility Lender Remedies for Loan Facility Declared Events of Default) of the Common Terms Agreement (including, subject to the Common Terms Agreement and the Common Security and Account Agreement, requiring the Borrower to deposit with the Credit Facility Agent an amount in the LC Cash Collateral Account equal to one hundred two percent (102%) of the amount available to be drawn under all Letters of Credit then outstanding), each of which is incorporated by reference and shall apply mutatis mutandis to this

 

43


Section 9.03 (Action Upon Event of Default) as if fully set forth herein; provided that, nothing herein shall, upon the occurrence of a Loan Facility Event of Default under Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement, require any certification, declaration or other notice prior to the deemed declaration of such Loan Facility Declared Default or the acceleration of the Loans in connection with the occurrence thereof as provided under Section 16.1(b) (Facility Lender Remedies for Loan Facility Declared Events of Default - Initiating Percentage for Enforcement Action with Respect to Collateral) of the Common Terms Agreement.

(b) Subject to Section 10.5 (Certain Agreements with Respect to Bankruptcy) of the Common Security and Account Agreement, following commencement of any Bankruptcy Proceeding by or against either Obligor or Pledgor, any Lender may: (i) file a claim or statement of interest with respect to (and to the extent of) the Senior Debt Obligations (if any) owed by such person to such Lender or Issuing Bank in accordance with the Finance Documents, (ii) vote on any plan of reorganization and (iii) make other filings, arguments, objections and motions in connection with such Bankruptcy Proceeding, in each case in accordance with the terms of the Finance Documents (other than any requirement for an intercreditor vote to take such action).

(c) Any termination and acceleration made pursuant to this Section 9.03 (Action Upon Event of Default) and Section 16.1(a)(ii) (Facility Lender Remedies for Loan Facility Declared Events of Default – Enforcement Action) of the Common Terms Agreement may, should the Required Lenders in their sole and absolute discretion so elect, be rescinded by written notice to the Borrower at any time after the principal of the Loans has become due and payable, but before any judgment or decree for the payment of the monies so due, or any part thereof, has been entered; provided that, no such rescission or annulment shall extend to or affect any subsequent Loan Facility Event of Default or impair any right consequent thereon.

(d) An event of default under this Credit Facility Agreement shall be deemed to be declared, in respect of any Loan Facility Event of Default referred to in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement, immediately and automatically upon its occurrence, without the requirement for any certification, declaration or other notice from a Term Lender or the Intercreditor Agent or any Senior Creditor in accordance with Section 15.2(a) (Declaration of Loan Facility Declared Default) of the Common Terms Agreement.

(e) Promptly after any Lender obtains knowledge of any Loan Facility Event of Default, such Lender shall notify the Credit Facility Agent in writing of such Loan Facility Event of Default, which notice shall describe such Loan Facility Event of Default in reasonable detail (including the date of occurrence of the same), specifically refer to this Section 9.03(e) (Action Upon Event of Default) and indicate that such notice is a notice of default.

Section 9.04 Cash Collateralization of Letters of Credit. Subject to the Common Terms Agreement and the Common Security and Account Agreement:

(a) Amounts held in the LC Cash Collateral Account shall be the property of the Credit Facility Agent for the benefit of the Issuing Banks and Working Capital Lenders and shall be applied by the Credit Facility Agent to the repayment of LC Loans deemed made under any Letters of Credit.

 

44


(b) The balance, if any, in the LC Cash Collateral Account, after all Letters of Credit shall have expired with no pending drawings or been fully drawn upon and giving effect to the payment of any LC Loans pursuant to Section 9.04(a) (Cash Collateralization of Letters of Credit), shall be applied to repay the other Loan Obligations according to Section 9.05 (Application of Proceeds).

Section 9.05 Application of Proceeds. Subject to the terms of the Intercreditor Agreement, any moneys received by the Credit Facility Agent from the Collateral Agent after the occurrence and during the continuance of a Loan Facility Event of Default and the period during which remedies have been initiated shall be applied in full or in part by the Credit Facility Agent against the Loan Obligations in accordance with Section 6.7(b) (Enforcement Proceeds Account) of the Common Security and Account Agreement (but without prejudice to the right of the Lenders or the Issuing Banks, subject to the terms of the Intercreditor Agreement, to recover any shortfall from the Borrower).

ARTICLE X

THE CREDIT FACILITY AGENT

Section 10.01 Appointment and Authority.

(a) Each of the Lenders and each of the Issuing Banks hereby appoints, designates and authorizes Natixis, New York Branch as its Credit Facility Agent under and for purposes of each Finance Document to which the Credit Facility Agent is a party, and in its capacity as the Credit Facility Agent, to act on its behalf as Senior Creditor Group Representative and the Designated Voting Party (as defined in the Intercreditor Agreement) for the Lenders and Issuing Banks. Natixis, New York Branch hereby accepts this appointment and agrees to act as the Credit Facility Agent for the Lenders and Issuing Banks in accordance with the terms of this Agreement. Each Lender and Issuing Bank hereby appoints and authorizes the Credit Facility Agent to execute and enter into each of the Common Terms Agreement, Intercreditor Agreement and Common Security and Account Agreement, and each other Finance Document to which it is party, on behalf of such Lender and such Issuing Bank, in its name, place and stead, to bind it to the representations, warranties, terms and conditions contained therein and to act on behalf of such Lender or such Issuing Bank under each Finance Document to which it is a party and in the absence of other written instructions from the Required Lenders received from time to time by the Credit Facility Agent (with respect to which the Credit Facility Agent agrees that it will comply, except as otherwise provided in this Section 10.01 (Appointment and Authority) or as otherwise advised by counsel, and subject in all cases to the terms of the Intercreditor Agreement), to exercise such powers hereunder and thereunder as are specifically delegated to or required of the Credit Facility Agent by the terms hereof and thereof, together with such powers as may be reasonably incidental thereto. Where the Credit Facility Agent is required or permitted to act under this Agreement or under any other Finance Document, the Credit Facility Agent shall, notwithstanding anything herein or therein to the contrary, (i) be entitled to request instruction or direction in respect of any

 

45


such rights, powers and discretions or clarification of any written instruction received by it, as to whether, and in what manner, it should exercise or refrain from exercising its rights, powers and discretions and (ii) unless the terms of the agreement unambiguously mandate the action, may refrain from acting (and will incur no liability in refraining to act) until that direction, instruction or clarification is received by it from the relevant parties or from a court of competent jurisdiction. Without limiting the generality of the foregoing sentence, the use of the term “agent” in this Agreement with reference to the Credit Facility Agent is not intended to connote any fiduciary or other implied (or express) obligations arising under agency doctrine of any applicable Government Rule. Instead, such term is used merely as a matter of market custom, and is intended to create or reflect only an administrative relationship between independent contracting parties.

(b) Except to the extent that the Credit Facility Agent is acting on express instructions, the Credit Facility Agent shall exercise such of the rights and powers vested in it by this Agreement, and use the same degree of care and skill in their exercise as a prudent Person would exercise or use under the circumstances in the conduct of his or her own affairs (taking into account the interests of all the Lenders and Issuing Banks benefiting from this Agreement). Nothing in this Agreement or any other Finance Document shall, in any case in which the Credit Facility Agent has failed to show such degree of care and skill, exempt the Credit Facility Agent from or indemnify it against any liability arising out of its own gross negligence, fraud or willful misconduct in relation to its duties under this Agreement or any other Finance Document as determined by a court of competent jurisdiction in a final non-appealable judgment.

(c) The Credit Facility Agent may not begin any legal action or proceeding in the name of a Lender or Issuing Bank, except as specifically permitted under the terms of this Agreement or the other Finance Documents.

(d) The provisions of this Article X (The Credit Facility Agent) are solely for the benefit of the Credit Facility Agent, the Lenders and the Issuing Banks, and neither the Borrower nor any other Person shall have rights as a third party beneficiary of any of such provisions other than the Borrower’s rights under Section 10.07(a) and (b) (Resignation or Removal of Credit Facility Agent) and Section 10.13 (Agreement to Comply with Finance Documents).

Section 10.02 Rights as a Facility Lender or Hedging Bank. Each Person serving as the Credit Facility Agent hereunder or under any other Finance Document shall have the same rights and powers in its capacity as a Facility Lender or Hedging Bank, as the case may be, as any other Facility Lender or Hedging Bank, as the case may be, and may exercise the same as though it were not the Credit Facility Agent. Each such Person and its Affiliates may accept deposits from, lend money to, act as the financial advisor or in any other advisory capacity for and generally engage in any kind of business with the Borrower or Affiliates of the Borrower as if such Person were not the Credit Facility Agent hereunder and without any duty to account therefor to the Lenders and Issuing Banks.

 

46


Section 10.03 Exculpatory Provisions.

(a) The Credit Facility Agent shall not have any duties or obligations except those expressly set forth herein and in the other Finance Documents. Without limiting the generality of the foregoing, the Credit Facility Agent shall not:

(i) be subject to any fiduciary or other implied duties (except for an implied covenant of good faith), regardless of whether a Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing;

(ii) have any duty to take any discretionary action or exercise any discretionary powers, except discretionary rights and powers expressly contemplated hereby or by the other Finance Documents that the Credit Facility Agent is required to exercise as directed in writing by the Required Lenders (or such other number or percentage of the Lenders as shall be expressly provided for herein or in the other Finance Documents); provided that, the Credit Facility Agent shall not be required to take any action that, in its opinion or the opinion of its counsel, may expose the Credit Facility Agent to liability or that is contrary to any Finance Document or applicable Government Rule; or

(iii) except as expressly set forth herein and in the other Finance Documents, have any duty to disclose, nor shall the Credit Facility Agent be liable for any failure to disclose, any information relating to the Borrower or any of its Affiliates that is communicated to or obtained by the Person serving as the Credit Facility Agent or any of its Affiliates in any capacity.

(b) The Credit Facility Agent shall not be liable for any action taken or not taken by it (i) with the prior written consent or at the request of the Required Lenders (or such other number or percentage of the Lenders or the Issuing Banks as may be necessary, or as the Credit Facility Agent may believe in good faith to be necessary, under the circumstances as provided in Section 11.01 (Decisions; Amendments, Etc.)) or (ii) in the absence of its own gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction by a final and non- appealable order. The Credit Facility Agent shall not be deemed to have knowledge or notice of the occurrence of any Loan Facility Event of Default unless the Credit Facility Agent has received a written notice in accordance with Section 9.03(e) (Action Upon Event of Default) or with Section 2.4(d) (Defaults) of the Intercreditor Agreement or from the Intercreditor Agent, the Obligors, the Pledgor or a Senior Creditor Group Representative referring to this Credit Facility Agreement, describing events or actions constituting a Loan Facility Event of Default and indicating that such notice is a notice of default. If the Credit Facility Agent receives such a notice of the occurrence of any Loan Facility Event of Default, the Credit Facility Agent shall give notice thereof to the Lenders, the Issuing Banks and the Intercreditor Agent. Subject to Article 16 (Common Remedies and Enforcement) of the Common Terms Agreement, the Credit Facility Agent shall take such action with respect to such Loan Facility Event of Default as is provided in Article IX (Default and Enforcement).

(c) The Credit Facility Agent shall not be responsible for or have any duty to ascertain or inquire into (i) any statement, warranty or representation made in or in connection with this Agreement or any other Finance Document, (ii) the contents of any certificate, report or other document delivered hereunder or thereunder or in connection herewith or therewith, (iii) the performance or observance of any of the covenants, agreements or other terms or conditions set forth herein or therein or the occurrence or Continuance of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default, (iv) the validity, enforceability, effectiveness or genuineness of this Agreement, any other Finance Document or any other agreement, instrument

 

47


or document, or the perfection or priority of any Lien or security interest created or purported to be created by any Security Document, (v) the nature or sufficiency of any payment received by the Credit Facility Agent, or to present or file any claim or notice, or to take any action with respect to the Collateral or any part thereof or the moneys due or to become due in respect thereof or any property covered thereby, or (vi) the satisfaction of any condition set forth in Article VII (Conditions Precedent) or elsewhere herein, other than to confirm receipt of any items expressly required to be delivered to the Credit Facility Agent, except those irregularities or errors of which the Credit Facility Agent has actual knowledge; provided that, nothing herein shall constitute a waiver by any Obligor or any Lender or any Issuing Banks of any of their rights against the Credit Facility Agent as a result of its gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final non-appealable judgment. If any remittance or communication received by the Credit Facility Agent appears manifestly erroneous or irregular to the Credit Facility Agent, it shall be under a duty to make prompt inquiry to the Person originating such remittance or communication in order to determine whether a clerical error or inadvertent mistake has occurred.

(d) The Credit Facility Agent shall not be liable to the Obligors for any breach by any Lender or any Issuing Bank of this Agreement or any other Finance Document (other than by the Facility Agent’s own gross negligence, willful misconduct or fraud as determined by a court of competent jurisdiction in a final and nonappealable judgment) or be liable to any Lender or any Issuing Bank for any breach by any Obligor of this Agreement or any other Finance Document.

Section 10.04 Reliance by Credit Facility Agent.

(a) The Credit Facility Agent shall be entitled to rely upon, and shall not incur any liability for relying upon, any notice, request, certificate, consent, statement, instrument, document or other writing (including any electronic message, internet or intranet website posting or other distribution) believed by it to be genuine and to have been signed, sent or otherwise authenticated by the proper Person. The Credit Facility Agent also may rely upon any statement made to it orally or by telephone and believed by it to have been made by the proper Person, and shall not incur any liability for relying thereon. In determining compliance with any condition hereunder to the making of a Loan or issuance of a Letter of Credit that by its terms must be fulfilled to the satisfaction of each Lender, each Issuing Bank or the Required Lenders, the Credit Facility Agent may presume that such condition is satisfactory to such Lender, such Issuing Bank or the Required Lenders, as the case may be, unless the Credit Facility Agent has received notice to the contrary from such Lender, such Issuing Bank or the Required Lenders or the Intercreditor Agent prior to the making of such Loan or issuance of such Letter of Credit. The Credit Facility Agent may consult with legal counsel, independent accountants and other experts selected by it, and shall not be liable for any action taken or not taken by it in accordance with the advice of any such counsel, accountants or experts. The Credit Facility Agent shall not be responsible for the negligence or misconduct of any legal counsel, independent accountants and other experts selected by it in good faith, and shall not be required to make any investigation as to the accuracy or sufficiency of any such advice or services; provided that, nothing herein shall constitute a waiver by the Obligors, the Lenders or the Issuing Banks of any of their rights against (i) the Credit Facility Agent as a result of its gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final, non-appealable judgment or (ii) such counsel, accountants or other experts.

 

48


(b) Each Obligor, each Lender and each Issuing Bank shall deliver to the Credit Facility Agent (or, in the case of the Obligors, deliver to the Intercreditor Agent for delivery to each Facility Agent) a list of authorized signatories, together, in the case of the Obligors, with a certificate of an officer of such party certifying the names and true signatures of such authorized signatories who are authorized to sign any notice, certificate, instrument, demand, request, direction, instruction, waiver, receipt, consent, agreement or other document or communication furnished to the Credit Facility Agent hereunder or under the other Finance Documents and the Credit Facility Agent shall be entitled to rely conclusively on such list until a new list is furnished by an Obligor, a Lender or an Issuing Bank, as the case may be, to the Credit Facility Agent (or, in the case of the Obligors, to the Intercreditor Agent for delivery to each Facility Agent).

Section 10.05 Delegation of Duties. The Credit Facility Agent may perform any and all of its duties and exercise any and all its rights and powers hereunder or under any other Finance Document by or through any one or more sub-agents appointed by the Credit Facility Agent. The Credit Facility Agent and any such sub-agent may perform any and all of its duties and exercise its rights and powers by or through their respective Related Parties. The exculpatory provisions of this Article X (The Credit Facility Agent) shall apply to any such sub-agent and to the Related Parties of the Credit Facility Agent, and shall apply to all of their respective activities in connection with their acting as or for the Credit Facility Agent.

Section 10.06 Indemnification by the Lenders. Without limiting the obligations of the Obligors hereunder or under the other Finance Documents, each Lender agrees that it shall, from time to time on demand by the Credit Facility Agent, indemnify the Credit Facility Agent and its Related Parties (ratably in accordance with its then applicable proportionate share) for any and all liabilities, obligations, losses, damages, penalties, actions, judgments, suits, costs, expenses (including reasonable legal fees) or disbursements of any kind or nature whatsoever, which may at any time be imposed on, incurred by or asserted against the Credit Facility Agent or any of its Related Parties in any way relating to or arising out of this Agreement, the other Finance Documents or any documents contemplated by or referred to herein or therein or the transactions contemplated hereby or thereby or the enforcement of any of the terms hereof or thereof or of any such other documents; provided that, no Lender shall be liable for any of the foregoing to the extent they arise solely from the Credit Facility Agent’s gross negligence, fraud or willful misconduct as determined by a final non-appealable judgment of a court of competent jurisdiction. The Credit Facility Agent shall be fully justified in taking, refusing to take or continuing to take any action hereunder unless it shall first be indemnified to its satisfaction by the Lenders against any and all liability and expense which may be incurred by it by reason of taking, refusing to take or continuing to take any such action. Without limitation of the foregoing, each Lender agrees to reimburse, ratably in accordance with all its Commitments, the Credit Facility Agent promptly upon demand for any out-of-pocket expenses (including counsel fees) incurred by the Credit Facility Agent in connection with the preparation, execution, administration, amendment, waiver, modification or enforcement of, or legal advice in respect of rights or responsibilities under, the Finance Documents, to the extent that the Credit Facility Agent is not reimbursed promptly for such expenses by the Obligors in accordance with the Finance Documents; provided that, upon recovery of any or all of such costs and expenses by the Credit Facility Agent from the Obligors, the Credit Facility Agent shall remit to each Lender that has paid such costs and expenses to the Credit Facility Agent pursuant to this Section 10.06 (Indemnification by the Lenders) its ratable share of

 

49


such amounts so recovered. The obligation of the Lenders to make payments pursuant to this Section 10.06 (Indemnification by the Lenders) is several and not joint or joint and several, and the same shall survive the payment in full of the Loan Obligations and the termination of this Agreement and the other Finance Documents.

Section 10.07 Resignation or Removal of Credit Facility Agent.

(a) The Credit Facility Agent may resign from the performance of all its functions and duties hereunder and under the other Finance Documents at any time by giving thirty (30) days’ prior notice to the Borrower, the Lenders and the Issuing Banks. The Credit Facility Agent may be removed at any time (i) by the Required Lenders for such Person’s gross negligence, fraud or willful misconduct or (ii) by the Borrower, with the consent of the Required Lenders and so long as no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing, for such Person’s gross negligence, fraud or willful misconduct. In the event Natixis, New York Branch is no longer the Credit Facility Agent, any successor Credit Facility Agent may be removed at any time with cause by the Required Lenders. Any such resignation or removal shall take effect upon the appointment of a successor Credit Facility Agent, in accordance with this Section 10.07 (Resignation or Removal of Credit Facility Agent) and Section 19.3 (Replacement of Facility Agents) of the Common Terms Agreement.

(b) Upon any notice of resignation by the Credit Facility Agent or upon the removal of the Credit Facility Agent by the Required Lenders, or by the Borrower with the approval of the Required Lenders pursuant to Section 10.07(a) (Resignation or Removal of Credit Facility Agent), the Required Lenders shall appoint a successor Credit Facility Agent, hereunder and under each other Finance Document to which the Credit Facility Agent is a party, such successor Credit Facility Agent to be a commercial bank or financial institution having combined capital and surplus of at least $1,000,000,000; provided that, if no Loan Facility Event of Default or Unmatured Loan Facility Event of Default shall then be Continuing, the appointment of a successor Credit Facility Agent shall also be subject to the prior written consent of the Borrower (such acceptance not to be unreasonably withheld, conditioned or delayed). The fees payable by the Borrower to a successor Credit Facility Agent shall be the same as those payable to its predecessor unless otherwise agreed between the Borrower and such successor.

(c) If no successor Credit Facility Agent shall have been so appointed and shall have accepted such appointment within sixty (60) days after (i) the retiring Credit Facility Agent gives notice of its resignation or (ii) the date fixed for such removal, as applicable, the Credit Facility Agent shall, at the expense of the Obligors, petition any court of competent jurisdiction in the United States for the appointment of a successor Credit Facility Agent. Such court may thereupon, after such notice, if any, as it may prescribe, appoint a successor Credit Facility Agent. If no successor Credit Facility Agent shall have been so appointed in accordance with clauses (a) and (b) above or (A) this clause (c) and shall have accepted such appointment within ninety (90) days or (B) in the case of this clause (c) if the Credit Facility Agent, acting reasonably, cannot determine a court of competent jurisdiction in the United States that will consider the petition contemplated in this clause (c) within sixty (60) days, in each case after (x) the retiring Credit Facility Agent gives notice of its resignation or (y) the date fixed for such removal, as applicable, the Credit Facility Agent may, at the expense of the Obligors, appoint a successor Credit Facility Agent

 

50


meeting the criteria set forth in Section 10.07(b) (Resignation or Removal of Credit Facility Agent); provided that, if no Loan Facility Event of Default shall then be Continuing, the appointment of such successor Credit Facility Agent shall also be subject to the prior written consent of the Borrower (such acceptance not to be unreasonably withheld, conditioned or delayed); provided further that, if no successor Credit Facility Agent shall have been so appointed by the Credit Facility Agent within thirty (30) days after the termination of such 90-day period, the Obligors may appoint a successor Credit Facility Agent with the consent of the Required Lenders (such consent not to be unreasonably withheld or delayed).

(d) Upon the acceptance of a successor’s appointment as Credit Facility Agent hereunder and compliance with the provisions of Section 19.3 (Replacement of Facility Agents) of the Common Terms Agreement, such successor shall succeed to and become vested with all of the rights, powers, privileges and duties of the retiring (or removed) Credit Facility Agent, and the retiring (or removed) Credit Facility Agent shall be discharged from all of its duties and obligations hereunder or under the other Finance Documents. After the retirement or removal of the Credit Facility Agent hereunder and under the other Finance Documents, the provisions of this Article X (The Credit Facility Agent) and Section 11.07 (Indemnification by the Obligors) shall continue in effect for the benefit of such retiring (or removed) Person, its sub-agents and their respective Related Parties in respect of any actions taken or omitted to be taken by any of them while the retiring Person was acting in its capacity as Credit Facility Agent.

(e) Notwithstanding anything in this Agreement, no resignation or, as the case may be, removal of the Credit Facility Agent shall be effective until the following conditions are satisfied:

(i) the Credit Facility Agent has transferred to its successor all the rights and obligations in its capacity as Credit Facility Agent under this Credit Facility Agreement, the Common Terms Agreement and the other Finance Documents to which it is party as the Credit Facility Agent; and

(ii) the requirements of Section 19.3 (Replacement of Facility Agents) of the Common Terms Agreement have been satisfied.

Section 10.08 No Amendment to Duties of Credit Facility Agent Without Consent. The Credit Facility Agent shall not be bound by any waiver, amendment, supplement or modification of this Agreement or any other Finance Document that affects its rights or duties hereunder or thereunder unless such Credit Facility Agent shall have given its prior written consent, in its capacity as Credit Facility Agent thereto.

Section 10.09 Non-Reliance on Credit Facility Agent, Lenders and Issuing Banks. Each of the Lenders and Issuing Banks acknowledges that it has, independently and without reliance upon the Credit Facility Agent, any other Lender or Issuing Bank or any of their Related Parties and based on such documents and information as it has deemed appropriate, made its own credit analysis and decision to enter into this Agreement and make its extensions of credit. Each of the Lenders and Issuing Banks also acknowledges that it will, independently and without reliance upon the Credit Facility Agent or any other Lender or Issuing Bank or any of their Related Parties and based on such documents and information as it shall from time to time deem appropriate, continue to make its own decisions in taking or not taking action under or based upon this Agreement, any other Finance Document or any related agreement or any document furnished hereunder or thereunder.

 

51


Section 10.10 No Coordinating Lead Arranger or Documentation Bank Duties. Anything herein to the contrary notwithstanding, no Coordinating Lead Arranger or Documentation Bank shall have any powers, duties or responsibilities under this Agreement, except in its capacity, as applicable, as the Credit Facility Agent or Lender or Issuing Bank hereunder.

Section 10.11 Copies. The Credit Facility Agent shall give prompt notice to each Lender and each Issuing Bank of receipt of each notice or request required or permitted to be given to the Credit Facility Agent by the Obligors pursuant to the terms of this Agreement or any other Finance Document (unless concurrently delivered to the Lenders by such Obligor). The Credit Facility Agent will distribute to each Lender and each Issuing Bank each document or instrument (including each document or instrument delivered by the Obligors to the Credit Facility Agent pursuant to Article VI (Representations and Warranties), Article VII (Conditions Precedent) and Article VIII (Covenants)) received for the account of the Credit Facility Agent and copies of all other communications received by the Credit Facility Agent from the Obligors for distribution to the Lenders and the Issuing Banks by the Credit Facility Agent in accordance with the terms of this Agreement or any other Finance Document.

Section 10.12 General Provisions as to Payments.

(a) Subject to Section 4.16 (Pro Rata Treatment), the Credit Facility Agent promptly shall distribute to each Lender and each Issuing Bank its pro rata share of each payment of (i) principal and interest payable to the Lenders or Issuing Banks on the Loans, (ii) fees hereunder received by the Credit Facility Agent for the account of the Lenders or the Issuing Banks and (iii) any other Loan Obligations. The payments made for the account of each Lender and each Issuing Bank shall be made and distributed to such Lender or Issuing Bank for the account of its facility office set forth in the Common Terms Agreement. Each Lender and each Issuing Bank shall have the right to alter its designated facility office upon written notice to the Credit Facility Agent, the Obligors and the Intercreditor Agent pursuant to Section 11.10 (Notices and Other Communications).

(b) Where a sum is to be paid to a Lender or Issuing Bank under the Finance Documents or another party to this Agreement by another party to this Agreement that is primarily liable for such sum, the Credit Facility Agent shall not be obliged to pay such sum to such other party (or to enter into or perform any related exchange contract) until it has established to its satisfaction that it has received such sum.

(c) If the Credit Facility Agent pays an amount to another party to this Agreement and it proves to be the case that the Credit Facility Agent had not actually received that amount for which another party to this Agreement is primarily liable, then the party to whom that amount (or the proceeds of any related exchange contract) was paid by the Credit Facility Agent shall on demand refund the same to the Credit Facility Agent together with interest on that amount from the date of payment to the date of receipt by the Credit Facility Agent, calculated by the Credit Facility Agent to reflect its cost of funds.

 

52


(d) The Credit Facility Agent acknowledges and agrees that, notwithstanding any provision to the contrary in any Finance Document, in no event shall the Lenders or Issuing Banks be obligated to pay any agency or other fee to the Credit Facility Agent even if the Obligors fail to do so.

Section 10.13 Agreement to Comply with Finance Documents. Each of the Lenders and Issuing Banks agrees for the benefit of the Borrower and each other that, in giving instructions to the Credit Facility Agent and the Intercreditor Agent and, where so permitted under this Agreement, the Intercreditor Agreement, Common Terms Agreement or the Common Security and Account Agreement, in taking Decisions by itself or through the Credit Facility Agent, including pursuing any Lender or Issuing Bank remedies against the Borrower, that such Lender or Issuing Bank shall act at all times in accordance with the terms of the Intercreditor Agreement, the Common Security and Account Agreement, the Common Terms Agreement, this Agreement and the applicable Finance Documents.

Section 10.14 Certain ERISA Matters.

(a) Each Lender and Issuing Bank (x) represents and warrants, as of the date such Person became a Lender or Issuing Bank party hereto, to, and (y) covenants, from the date such Person became a Lender or Issuing Bank party hereto to the date such Person ceases being a Lender or Issuing Bank party hereto, for the benefit of, the Credit Facility Agent and not, for the avoidance of doubt, to or for the benefit of the Borrower, that at least one of the following is and will be true:

(i) such Lender or Issuing Bank is not using “plan assets” (within the meaning of Section 3(42) of ERISA or otherwise) of one or more Benefit Plans with respect to such Lender’s entrance into, participation in, administration of and performance of the Loans, the Letters of Credit, the Commitments or this Agreement;

(ii) the transaction exemption set forth in one or more PTEs, such as PTE 84- 14 (a class exemption for certain transactions determined by independent qualified professional asset managers), PTE 95-60 (a class exemption for certain transactions involving insurance company general accounts), PTE 90-1 (a class exemption for certain transactions involving insurance company pooled separate accounts), PTE 91-38 (a class exemption for certain transactions involving bank collective investment funds) or PTE 96- 23 (a class exemption for certain transactions determined by in-house asset managers), is applicable with respect to such Lender’s or Issuing Bank’s entrance into, participation in, administration of and performance of the Loans, the Letters of Credit, the Commitments and this Agreement;

(iii) (A) such Lender or Issuing Bank is an investment fund managed by a “Qualified Professional Asset Manager” (within the meaning of Part VI of PTE 84-14), (B) such Qualified Professional Asset Manager made the investment decision on behalf of such Lender to enter into, participate in, administer and perform the Loans, the Letters of Credit, the Commitments and this Agreement, (C) the entrance into, participation in, administration of and performance of the Loans, the Letters of Credit, the Commitments and this Agreement satisfies the requirements of sub-sections (b) through (g) of Part I of PTE 84-14, and (D) to the best knowledge of such Lender or Issuing Bank, the requirements of subsection (a) of Part I of PTE 84-14 are satisfied with respect to such Lender’s or Issuing Bank’s entrance into, participation in, administration of and performance of the Loans, the Letters of Credit, the Commitments and this Agreement; or

 

53


(iv) such other representation, warranty and covenant as may be agreed in writing between the Credit Facility Agent, in its sole discretion, and such Lender or Issuing Bank.

(b) In addition, unless either (A) sub-clause (i) in the immediately preceding clause (a) is true with respect to a Lender or Issuing Bank, as applicable, or (B) a Lender has provided another representation, warranty and covenant in accordance with sub-clause (iv) in the immediately preceding clause (a), such Lender or Issuing Bank further (x) represents and warrants, as of the date such Person became a Lender or Issuing Bank party hereto, to, and (y) covenants, from the date such Person became a Lender or Issuing Bank party hereto to the date such Person ceases being a Lender or Issuing Bank party hereto, for the benefit of, the Credit Facility Agent and not, for the avoidance of doubt, to or for the benefit of the Borrower, that the Credit Facility Agent is not a fiduciary with respect to the assets of such Lender or Issuing Bank involved in such Lender’s or Issuing Bank’s entrance into, participation in, administration of and performance of the Loans, the Letters of Credit, the Commitments and this Agreement (including in connection with the reservation or exercise of any rights by the Credit Facility Agent under this Agreement, any Finance Document or any documents related hereto or thereto).

Section 10.15 Erroneous Payments.

(a) If the Credit Facility Agent (i) notifies a Lender or Issuing Bank, or any Person who has received funds on behalf of a Lender or Issuing Bank (any such Lender, Issuing Bank or other recipient (and each of their respective successors and assigns), a “Payment Recipient”) that the Credit Facility Agent has determined in its reasonable discretion (whether or not after receipt of any notice under immediately succeeding clause (b)) that any funds (as set forth in such notice from the Credit Facility Agent) received by such Payment Recipient from the Credit Facility Agent or any of its Affiliates were erroneously or mistakenly transmitted to, or otherwise erroneously or mistakenly received by, such Payment Recipient (whether or not known to such Lender, Issuing Bank or other Payment Recipient on its behalf) (any such funds, whether transmitted or received as a payment, prepayment or repayment of principal, interest, fees, distribution or otherwise, individually and collectively, an “Erroneous Payment”) and (ii) demands in writing the return of such Erroneous Payment (or a portion thereof), such Erroneous Payment shall at all times remain the property of the Credit Facility Agent pending its return or repayment as contemplated below in this Section 10.15 (Erroneous Payments) and held in trust for the benefit of the Credit Facility Agent, and such Lender or Issuing Bank shall (or, with respect to any Payment Recipient who received such funds on its behalf, shall cause such Payment Recipient to) promptly, but in no event later than two (2) Business Days thereafter (or such later date as the Credit Facility Agent may, in its sole discretion, specify in writing), return to the Credit Facility Agent the amount of any such Erroneous Payment (or portion thereof) as to which such a demand was made, in same day funds (in the currency so received), together with interest thereon (except to the extent waived in writing by the Credit Facility Agent) in respect of each day from and including the date such Erroneous Payment (or portion thereof) was received by such Payment Recipient to the date such amount is

 

54


repaid to the Credit Facility Agent in same day funds at the greater of the Federal Funds Effective Rate and a rate determined by the Credit Facility Agent in accordance with banking industry rules on interbank compensation from time to time in effect. A notice of the Credit Facility Agent to any Payment Recipient under this clause (a) shall be conclusive, absent manifest error.

(b) Without limiting immediately preceding clause (a), each Lender, Issuing Bank or any Person who has received funds on behalf of a Lender or Issuing Bank (and each of their respective successors and assigns), agrees that if it receives a payment, prepayment or repayment (whether received as a payment, prepayment or repayment of principal, interest, fees, distribution or otherwise) from the Credit Facility Agent (or any of its Affiliates) (x) that is in a different amount than, or on a different date from, that specified in this Agreement or in a notice of payment, prepayment or repayment sent by the Credit Facility Agent (or any of its Affiliates) with respect to such payment, prepayment or repayment, (y) that was not preceded or accompanied by a notice of payment, prepayment or repayment sent by the Credit Facility Agent (or any of its Affiliates), or (z) that such Lender or Issuing Bank, or other such recipient, otherwise becomes aware was transmitted, or received, in error or by mistake (in whole or in part), then in each such case:

(i) it acknowledges and agrees that (A) in the case of immediately preceding clause (x) or (y), an error and mistake shall be presumed to have been made (absent written confirmation from the Credit Facility Agent to the contrary) or (B) an error and mistake has been made (in the case of immediately preceding clause (z)), in each case, with respect to such payment, prepayment or repayment; and

(ii) such Lender or Issuing Bank shall (and shall use commercially reasonable efforts to cause any other recipient that receives funds on its respective behalf to) promptly (and, in all events, within one (1) Business Day of its knowledge of the occurrence of any of the circumstances described in immediately preceding clauses (x), (y) and (z)) notify the Credit Facility Agent of its receipt of such payment, prepayment or repayment, the details thereof (in reasonable detail) and that it is so notifying the Credit Facility Agent pursuant to this Section 10.15(b) (Erroneous Payments).

For the avoidance of doubt, the failure to deliver a notice to the Credit Facility Agent pursuant to this Section 10.15(b) (Erroneous Payments) shall not have any effect on a Payment Recipient’s obligations pursuant to Section 10.15(a) (Erroneous Payments) or on whether or not an Erroneous Payment has been made.

(c) Each Lender and Issuing Bank hereby authorizes the Credit Facility Agent to set off, net and apply any and all amounts at any time owing to such Lender or Issuing Bank under any Finance Document, or otherwise payable or distributable by the Credit Facility Agent to such Lender or Issuing Bank under any Finance Document with respect to any payment of principal, interest, fees or other amounts, against any amount that the Credit Facility Agent has demanded to be returned under Section 10.15(a) (Erroneous Payments).

(d) (i) In the event that an Erroneous Payment (or portion thereof) is not recovered by the Credit Facility Agent for any reason, after demand therefor in accordance with Section 10.15(a) (Erroneous Payments), from any Lender that has received such Erroneous Payment (or portion thereof) (and/or from any Payment Recipient who received such Erroneous Payment (or portion

 

55


thereof) on its respective behalf) (such unrecovered amount, an “Erroneous Payment Return Deficiency”), upon the Credit Facility Agent’s notice to such Lender at any time, then effective immediately (with the consideration therefor being acknowledged by the parties hereto), (A) such Lender shall be deemed to have assigned its Loans (but not its Commitments) with respect to which such Erroneous Payment was made (the “Erroneous Payment Impacted Class”) in an amount equal to the Erroneous Payment Return Deficiency (or such lesser amount as the Credit Facility Agent may specify) (such assignment of the Loans (but not Commitments) of the Erroneous Payment Impacted Class, the “Erroneous Payment Deficiency Assignment”) (on a cashless basis and such amount calculated at par plus any accrued and unpaid interest (with the assignment fee to be waived by the Credit Facility Agent in such instance)), and is hereby (together with the Borrower) deemed to execute and deliver a Lender Assignment Agreement with respect to such Erroneous Payment Deficiency Assignment, and such Lender shall deliver any Notes evidencing such Loans to the Borrower or the Credit Facility Agent (but the failure of such Person to deliver any such Notes shall not affect the effectiveness of the foregoing assignment), (B) the Credit Facility Agent as the assignee Lender shall be deemed to have acquired the Erroneous Payment Deficiency Assignment, (C) upon such deemed acquisition, the Credit Facility Agent as the assignee Lender shall become a Lender, as applicable, hereunder with respect to such Erroneous Payment Deficiency Assignment and the assigning Lender shall cease to be a Lender, as applicable, hereunder with respect to such Erroneous Payment Deficiency Assignment, excluding, for the avoidance of doubt, its obligations under the indemnification provisions of this Agreement and its applicable Commitments which shall survive as to such assigning Lender, (D) the Credit Facility Agent and the Borrower shall each be deemed to have waived any consents required under this Agreement to any such Erroneous Payment Deficiency Assignment, and (E) the Credit Facility Agent will reflect in the Register its ownership interest in the Loans subject to the Erroneous Payment Deficiency Assignment. For the avoidance of doubt, no Erroneous Payment Deficiency Assignment will reduce the Commitments of any Lender and such Commitments shall remain available in accordance with the terms of this Agreement.

(ii) Subject to Section 11.04 (Assignments) (but excluding, in all events, any assignment consent or approval requirements (whether from the Borrower or otherwise)), the Credit Facility Agent may, in its discretion, sell any Loans acquired pursuant to an Erroneous Payment Deficiency Assignment and upon receipt of the proceeds of such sale, the Erroneous Payment Return Deficiency owing by the applicable Lender shall be reduced by the net proceeds of the sale of such Loan (or portion thereof), and the Credit Facility Agent shall retain all other rights, remedies and claims against such Lender (and/or against any recipient that receives funds on its respective behalf). In addition, an Erroneous Payment Return Deficiency owing by the applicable Lender (A) shall be reduced by the proceeds of prepayments or repayments of principal and interest, or other distribution in respect of principal and interest, received by the Credit Facility Agent on or with respect to any such Loans acquired from such Lender pursuant to an Erroneous Payment Deficiency Assignment (to the extent that any such Loans are then owned by the Credit Facility Agent) and (y) may, in the sole discretion of the Credit Facility Agent, be reduced by any amount specified by the Credit Facility Agent in writing to the applicable Lender from time to time.

 

56


(e) The parties hereto agree that (A) irrespective of whether the Credit Facility Agent may be equitably subrogated, in the event that an Erroneous Payment (or portion thereof) is not recovered from any Payment Recipient that has received such Erroneous Payment (or portion thereof) for any reason, the Credit Facility Agent shall be subrogated to all the rights and interests of such Payment Recipient (and, in the case of any Payment Recipient who has received funds on behalf of a Lender or Issuing Bank, to the rights and interests of such Lender or Issuing Bank, as the case may be) under the Finance Documents with respect to such amount (the “Erroneous Payment Subrogation Rights”) (provided that, the Obligors’ Loan Obligations under the Finance Documents in respect of the Erroneous Payment Subrogation Rights shall not be duplicative of such Loan Obligations in respect of Loans that have been assigned to the Credit Facility Agent under an Erroneous Payment Deficiency Assignment), and (B) an Erroneous Payment shall not pay, prepay, repay, discharge or otherwise satisfy any Loan Obligations owed by the Borrower or any other Obligor; provided that, this Section 10.15(e) (Erroneous Payments) shall not be interpreted to increase (or accelerate the due date for), or have the effect of increasing (or accelerating the due date for), the Loan Obligations of the Borrower relative to the amount (and/or timing for payment) of the Loan Obligations that would have been payable had such Erroneous Payment not been made by the Credit Facility Agent; provided further that, for the avoidance of doubt, immediately preceding clauses (A) and (B) shall not apply to the extent any such Erroneous Payment is, and solely with respect to the amount of such Erroneous Payment that is, comprised of funds received by the Credit Facility Agent from the Borrower for the purpose of making such Erroneous Payment.

(f) To the extent permitted by applicable law, no Payment Recipient shall assert any right or claim to an Erroneous Payment, and hereby waives, and is deemed to waive, any claim, counterclaim, defense or right of set-off or recoupment with respect to any demand, claim or counterclaim by the Credit Facility Agent for the return of any Erroneous Payment received, including, without limitation, any defense based on “discharge for value” or any similar doctrine.

(g) Each party’s obligations, agreements and waivers under this Section 10.15 (Erroneous Payments) shall survive the resignation or replacement of the Credit Facility Agent, the termination of the Commitments and/or the repayment, satisfaction or discharge of all Loan Obligations (or any portion thereof) under any Finance Document.

ARTICLE XI

MISCELLANEOUS PROVISIONS

Section 11.01 Decisions; Amendments, Etc.

(a) Subject to the terms of the Intercreditor Agreement and the Common Security and Account Agreement, no Modification or termination of any provision of this Agreement or other Decision by Lenders or Issuing Banks under this Agreement shall be effective unless in writing signed by the Obligors and the Credit Facility Agent (acting on the instruction of the Required Lenders), and each such Modification, termination or Decision shall be effective only in the specific instance and for the specific purpose for which given; provided that:

 

57


(i) the consent of each Lender or each Issuing Bank directly and adversely affected thereby will be required with respect to:

(A) increases in or extensions (other than pursuant to Section 2.08 (Incremental Commitments) or with respect to incurrence of any Additional Senior Debt to which such Lender has agreed to participate) of or change to the order of application of any reduction in any Commitments or change to the order of application of any prepayment of Loans from the application thereof set forth in the applicable provisions of Section 2.07 (Termination or Reduction of Commitments), Section 4.11 (Voluntary Prepayment), Section 4.12 (Mandatory Prepayment) (it being understood that a waiver of any of the conditions in Section 7.01 (Conditions to Initial Closing), Section 7.02 (Conditions to Upsize Closing), Section 7.03 (Conditions to Each Term Loan Advance) or Section 7.04 (Conditions to Each Working Capital Advance) or waiver of any Loan Facility Event of Default, Unmatured Loan Facility Event of Default or mandatory prepayment will not constitute an increase or extension of any Commitment);

(B) reductions of the principal of, or the interest or rate of interest specified herein on, any Loan, or any Fees or other amounts (including reduction in the amount to be paid in respect of any mandatory prepayments under Section 4.12 (Mandatory Prepayment)) payable to any Lender or Issuing Bank hereunder (other than by virtue of a waiver of any of the conditions in Section 7.01 (Conditions to Initial Closing), Section 7.02 (Conditions to Upsize Closing), Section 7.03 (Conditions to Each Term Loan Advance) or Section 7.04 (Conditions to Each Working Capital Advance), Loan Facility Event of Default or Unmatured Loan Facility Event of Default or change to a financial ratio);

(C) extensions of the Final Maturity Date or Working Capital Loan Termination Date under this Agreement, any date scheduled for any payment of principal, fees, interest or amortization payment (as applicable) under Section 4.01 (Repayment of Term Loan Advances), Section 4.04 (Interest Payment Dates) or Section 4.15 (Fees) or mandatory payment under Section 4.12 (Mandatory Prepayment) (it being understood that a waiver of any condition precedent or the waiver of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default or change to a financial ratio will not constitute an extension of the Final Maturity Date); and

(D) Modifications to the provisions of Section 4.16 (Pro Rata Treatment) or Section 4.17 (Sharing of Payments);

(ii) the consent of each Lender and each Issuing Bank will be required with respect to:

(A) changes to any provision of this Section 11.01 (Decisions; Amendments, Etc.), the definition of Required Lenders, or any other provision hereof specifying the number or percentage of Lenders or Issuing Banks required to amend, waive, terminate or otherwise modify any rights hereunder or make any determination or grant any consent hereunder;

 

58


(B) releases or Modifications of all or a material portion of the Collateral from the Lien of any of the Security Documents (other than as permitted in the Finance Documents);

(C) releases of all or a substantial portion of the value of the Guarantee by the Guarantor under or in connection with this Agreement, the Common Terms Agreement, the Common Security and Account Agreement or any Security Document (other than as permitted in the Finance Documents);

(D) assignment or transfer by any Obligor of any of its rights and obligations under this Agreement except with respect to any such assignment or transfer expressly permitted under this Agreement, the Common Terms Agreement or the Common Security and Account Agreement;

(E) any of the amendments contemplated in Schedule 1(a), (b), (c), (d), (e), (f), (g), (h) and (i) (All Loan Facilities Decisions) of the Intercreditor Agreement; provided that, the consent of all Lenders will be required with respect to Schedule 1(b) (All Loan Facilities Decisions) of the Intercreditor Agreement only to the extent such amendment adversely affects the timing or priority of payments for Senior Debt Obligations in the cash waterfall in Section 4.7 (Cash Waterfall) of the Common Security and Account Agreement;

(F) satisfaction or waiver of each of the conditions in Section 7.01 (Conditions to Initial Closing) or Section 7.02 (Conditions to Upsize Closing); and

(G) any amendment, waiver, consent or other modification to subordinate the Loans to any other Indebtedness for borrowed money or subordinate any Lien securing the Loans on a material portion of the Collateral to any other Lien securing any other Indebtedness, in each case, except any “debtor- in-possession” facility without the consent of each Lender and each Issuing Bank; and

(iii) the consent of any Lender (other than any Lender that is an Obligor, the Pledgor or the Sponsor or an Affiliate thereof except as set forth in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement) will be sufficient with respect to any Modification, termination or Decision specified in a Finance Document as being made solely by any individual Senior Creditor.

(b) Except as set forth in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, no Lender that is an Obligor or the Sponsor or an Affiliate thereof shall cast a vote with respect to any Decision.

 

59


(c) In the event that the Credit Facility Agent is required to cast a vote with respect to a Decision under this Agreement or under Section 3.6 (Other Voting Considerations) of the Intercreditor Agreement and in each other instance in which the Lenders or Issuing Banks are required to vote or make a Decision, a vote shall be taken among the Lenders or Issuing Banks in the timeframe reasonably specified by the Credit Facility Agent (which timeframe shall expire at least two (2) Business Days prior to the expiration of the time period specified in the notice provided by the Intercreditor Agent to the Credit Facility Agent pursuant to Section 4.5(a)(iii) (Certain Procedures Relating to Modifications, Instructions, and Exercises of Discretion) of the Intercreditor Agreement).

(d) No vote shall be required for any Decision or other action permitted to be taken by any individual Lender or any individual Issuing Bank pursuant to Section 9.03(b) (Action Upon Event of Default) of this Agreement, and the Credit Facility Agent shall be authorized to act at the direction of any Lender or any Issuing Bank in respect of any such Decision or action.

(e) Subject to clause (f) below, in the event any Lender or any Issuing Bank does not cast its votes by the later of (i) the timeframe specified by the Credit Facility Agent pursuant to clause (c) above and (ii) ten (10) Business Days following receipt of the request for such vote or Decision, the Borrower shall be entitled to instruct the Credit Facility Agent to deliver a notice to such Lender or Issuing Bank, informing it that if it does not respond within an additional five (5) Business Days of the date of such notice (or such longer period as the Borrower may reasonably determine in consultation with the Credit Facility Agent), its vote shall be disregarded. If such Lender or Issuing Bank (A) has not advised the Credit Facility Agent within the time specified in the additional notice whether it approves or disapproves of the applicable Decision or (B) has advised the Credit Facility Agent that it has determined to abstain from voting on such Decision, such Lender or Issuing Bank shall be deemed to have waived its right to consent, approve, waive or provide direction with respect to such Decision and shall be excluded from the numerator and denominator of such calculation for the purpose of determining whether the Required Lenders have made a decision with respect to such action. Such Lender hereby waives any and all rights it may have to object to or seek relief from the decision of the Lenders voting with respect to such issue and agrees to be bound by such decision.

(f) The provisions of clauses (c) and (e) above do not apply to any action that requires the consent of 100% of the Lenders or Issuing Banks or the consent of each affected Lender and Issuing Bank, as applicable, as set forth in Section 11.01(a)(i) and (ii) (Decisions; Amendments, Etc.) above.

(g) The agreements contemplated by this Section 11.01 (Decisions; Amendments, Etc.) shall not be required for any update to the Amortization Schedule delivered in accordance with Section 4.01(b) (Repayment of Term Loan Advances) or Section 4.01(c) (Repayment of Term Loan Advances) (which amendments shall be effective, absent any manifest error, upon delivery by the Credit Facility Agent to the Borrower and Intercreditor Agent of the updated Amortization Schedule in accordance with the provisions of such Section).

(h) With respect to any modification, consent or waiver under any Finance Document requiring the vote of the Credit Facility Agent as Senior Creditor Group Representative of the Lenders and the Issuing Banks, such vote will be cast in accordance with the Intercreditor Agreement.

 

60


(i) Notwithstanding anything herein to the contrary, in the Common Terms Agreement or in the Common Security and Account Agreement to the contrary, the Lenders or Issuing Banks, or the Credit Facility Agent as Senior Creditor Group Representative, shall not be entitled to vote on any covenant or event of default in the Common Terms Agreement if such covenant or event of default expressly does not extend to the Lenders or the Issuing Banks under the terms of this Agreement.

(j) Notwithstanding anything herein to the contrary, each of the Lenders and Issuing Banks authorizes and instructs the Credit Facility Agent to make Administrative Decisions (as defined in the Intercreditor Agreement) with respect to this Agreement without the need for further authorization, consent or instruction from any Lender, Issuing Bank or other Credit Facility Secured Party with respect to such Administrative Decisions.

Section 11.02 Entire Agreement. This Agreement, the other Finance Documents and any agreement, document or instrument attached hereto or referred to herein integrate all the terms and conditions mentioned herein or incidental hereto and supersede all oral negotiations and prior writings in respect to the subject matter hereof.

Section 11.03 Applicable Government Rule; Jurisdiction; Etc.

(a) GOVERNING LAW. THIS AGREEMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK.

(b) SUBMISSION TO JURISDICTION. The provisions set forth in Section 23.14 (Consent to Jurisdiction) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

(c) Service of Process. Each party irrevocably consents to the service of any and all process in any such action or proceeding by the mailing of copies of such process to such Person at its then effective notice addresses pursuant to Section 11.10 (Notices and Other Communications).

(d) Immunity. The provisions set forth in Section 23.3 (Waiver of Immunity) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

(e) WAIVER OF JURY TRIAL. The provisions set forth in Section 23.13 (Waiver of Jury Trial) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

Section 11.04 Assignments.

(a) The provisions of this Agreement shall be binding upon and inure to the benefit of the parties hereto and their respective successors and assigns permitted hereby, except that none of the Obligors may assign or otherwise transfer any of its rights or obligations hereunder without the prior written consent of each of the Lenders, each of the Issuing Banks and the Credit Facility Agent (and any attempted assignment or other transfer by any Obligor without such consent shall

 

61


be null and void), and no Lender or Issuing Bank may assign or otherwise transfer any of its rights or obligations hereunder except (i) to an Acceptable Lender in accordance with Section 11.04(b) and Section 11.04(i) (Assignments), (ii) by way of participation in accordance with Section 11.04(d) through (f) (Assignments) or (iii) by way of pledge or assignment of a security interest subject to the restrictions of Section 11.04(g) (Assignments) (and any other attempted assignment or transfer by any party hereto shall be null and void).

(b) (i) Subject to Section 11.04(i), Section 11.04(j) and this Section 11.04(b) (Assignments), any Lender may at any time after the date hereof assign to one or more Acceptable Lenders all or a portion of its rights and obligations under this Agreement (including all or a portion of its Commitments and the Loans at the time owing to it and, if such Loans are LC Loans, an equal portion of its Non-Fronting Limit); provided that, during the Availability Period for any Type of Loans or Commitments subject to assignment, (A) any such Acceptable Lender is an Eligible Assignee or has a then-current credit rating of at least equivalent to Baa2 from Moody’s or BBB from S&P or, if applicable, an insurer whose financial strength rating is at least equivalent to Baa1 from Moody’s or BBB+ from S&P or is otherwise creditworthy in the opinion of the Borrower (acting reasonably) in light of the Commitments proposed to be assigned, transferred or novated and (B) if the assigning Working Capital Lender is an Issuing Bank, the assignee is an Eligible Assignee or meets the ratings criteria within the definition of Issuing Bank; provided further that, on the date of such assignment, such assignment would not result in an increase in amounts payable by the Borrower under Section 5.03 (Increased Costs) or Section 5.05 (Funding Losses), unless such increase in amounts payable measured on such date of assignment is waived by the assigning and assuming Lenders.

(ii) Assignments made pursuant to this Section 11.04(b) (Assignments) shall be made with the prior written approval of the Borrower (such approval not to be unreasonably withheld or delayed and to be deemed to have been given by the Borrower if the Borrower has not responded in writing within fifteen (15) Business Days of request) unless (A) such assignment is to a Person described in clauses (a) or (b) of the definition of “Eligible Assignee” or (B) a Loan Facility Event of Default has occurred and is Continuing; provided that, where the prior written approval of the Borrower is not required, the assigning Existing Facility Lender shall promptly notify the Borrower of any such assignment, novation or transfer.

(iii) Except in the case of (A) an assignment of the entire remaining amount of the assigning Lender’s Commitment of a certain Type and, if such assignment is of a Working Capital Commitment, the Working Capital Loans and LC Loans owing to it and its entire Non-Fronting Limit or (B) an assignment to a Lender, or an Affiliate of a Lender, or an Approved Fund with respect to a Lender, the sum of (x) the outstanding Commitments, if any, and (y) the outstanding Loans subject to each such assignment (determined as of the date the Lender Assignment Agreement with respect to such assignment is delivered to the Credit Facility Agent or, if “Trade Date” is specified in the Lender Assignment Agreement, as of the Trade Date) shall not be less than $5,000,000, in the case of Term Loans and Term Loan Commitments, and $1,000,000 in the case of Working Capital Commitments and, with respect to the assignment of the Term Loans, in integral multiples of $1,000,000, and with respect to the assignment of Working Capital Loans, in integral multiples of $500,000, unless the Credit Facility Agent otherwise consents in writing.

 

62


(iv) Subject to Section 11.04(g) and Section 11.04(i) (Assignments), each partial assignment shall be made as an assignment of the same percentage of outstanding Commitments and outstanding Loans of the same Type and a proportionate part of all the assigning Lender’s rights and obligations under this Agreement with respect to the Loan and the Commitment of the such Type.

(v) The parties to each assignment shall execute and deliver to the Credit Facility Agent a Lender Assignment Agreement, in the form of Exhibit E (Form of Lender Assignment Agreement), together with a processing and recordation fee of $3,500; provided that, (A) no such fee shall be payable in the case of an assignment to a Lender, an Affiliate of a Lender or an Approved Fund with respect to a Lender and (B) in the case of contemporaneous assignments by a Lender to one or more Approved Funds managed by the same investment advisor (which Approved Funds are not then Lenders hereunder), only a single such fee shall be payable for all such contemporaneous assignments.

(vi) If the Acceptable Lender is not a Lender prior to such assignment, it shall deliver to the Credit Facility Agent an administrative questionnaire and all documentation and other information required by bank regulatory authorities under applicable “know your customer” requirements.

(vii) In connection with any assignment of rights and obligations of any Defaulting Lender hereunder, no such assignment shall be effective unless and until, in addition to the other conditions thereto set forth herein, the parties to the assignment shall make such additional payments to the Credit Facility Agent in an aggregate amount sufficient, upon distribution thereof as appropriate (which may be outright payment, purchases by the assignee of participations or subparticipations, or other compensating actions, including funding, with the consent of the Borrower and the Credit Facility Agent, the applicable pro rata share of Loans previously requested but not funded by the Defaulting Lender, to each of which the applicable assignee and assignor hereby irrevocably consent), to (A) pay and satisfy in full all payment liabilities then owed by such Defaulting Lender to the Credit Facility Agent, and each other Lender hereunder (and interest accrued thereon), including any Issuing Bank pursuant to Section 3.02(e) (Reimbursement of Issuing Bank), and (B) acquire (and fund as appropriate) its full pro rata share of all Loans in accordance with its Commitment Percentage. Notwithstanding the foregoing, in the event that any assignment of rights and obligations of any Defaulting Lender hereunder shall become effective under applicable law without compliance with the provisions of this paragraph, then the assignee of such interest shall be deemed to be a Defaulting Lender for all purposes of this Agreement until such compliance occurs.

(viii) Subject to acceptance and recording thereof by the Credit Facility Agent pursuant to Section 11.04(c) (Assignments), from and after the effective date specified in each Lender Assignment Agreement, the Acceptable Lender thereunder shall be a party to this Agreement and, to the extent of the interest assigned by such Lender Assignment

 

63


Agreement, have the rights and obligations of a Lender under this Agreement and the other applicable Finance Documents, and the assigning Lender thereunder shall, to the extent of the interest assigned by such Lender Assignment Agreement, be released from its obligations under this Agreement and the other applicable Finance Documents (and, in the case of a Lender Assignment Agreement covering all of the assigning Lender’s rights and obligations under this Agreement, such Lender shall cease to be a party hereto or benefit from any Finance Document) but shall continue to be entitled to the benefits of Section 5.01 (Illegality), Section 5.03 (Increased Costs), Section 5.05 (Funding Losses) and Section 5.06 (Taxes) hereof, and Section 23.4 (Expenses) of the Common Terms Agreement and Section 12.18 (Other Indemnities) of the Common Security and Account Agreement with respect to facts and circumstances occurring prior to the effective date of such assignment; provided that, except to the extent otherwise expressly agreed by the affected parties, no assignment by a Defaulting Lender will constitute a waiver or release of any claim of any party hereunder arising from that Lender’s having been a Defaulting Lender.

(ix) Upon request, the Borrower (at its expense) shall execute and deliver a Note to the assignee Lender and/or a revised Note to the assigning Lender reflecting such assignment.

(x) Any assignment or transfer by a Lender of rights or obligations under this Agreement that does not comply with this Section 11.04(b) (Assignments) shall be treated for purposes of this Agreement as a sale by such Lender of a participation in such rights and obligations in accordance with Section 11.04(d) through (f) (Assignments). Any assignment or transfer by an Issuing Bank of rights or obligations under this Agreement that does not comply with this Section 11.04(b) (Assignments) and Section 3.05 (Resignation as an Issuing Bank), as applicable, shall be null and void. Upon any such assignment, the Credit Facility Agent will deliver a notice thereof to the Borrower (provided that, failure to deliver such notice shall not result in any liability for the Credit Facility Agent).

(xi) Any assignment of the Base Term Loan Commitment or the Contingency Reserve Term Loan Commitment shall be accompanied by a pro rata assignment of the Contingency Reserve Term Loan Commitment or the Base Term Loan Commitments, respectively.

(c) The Credit Facility Agent shall maintain the Register in accordance with Section 2.06(e) (Funding).

(d) Any Lender may at any time, without the consent of, or notice to, the Borrower or the Credit Facility Agent, sell participations to a Participant (other than a Disqualified Institution) in all or a portion of such Lender’s rights or obligations under this Agreement (including all or a portion of its Commitments or the Loans under this Agreement owing to it); provided that, (i) such Lender’s obligations under this Agreement shall remain unchanged, (ii) such Lender shall remain solely responsible to the other parties hereto for the performance of such obligations and (iii) the Borrower, the Credit Facility Agent and the other Lenders shall continue to deal solely and directly

 

64


with such Lender in connection with such Lender’s rights and obligations under this Agreement. For the avoidance of doubt, each Lender shall be responsible for the indemnity under Section 10.06 (Indemnification by the Lenders) with respect to any payments made by such Lender to its Participant(s).

(e) Any agreement or instrument pursuant to which a Lender sells such a participation shall provide that such Lender shall retain the sole right to enforce this Agreement and to approve any amendment, modification or waiver of any provision of this Agreement; provided that, such agreement or instrument may provide that such Lender will not, without the consent of the Participant, agree to any amendment, waiver or other modification described in the first proviso to Section 11.01 (Decisions; Amendments, Etc.) that directly affects such Participant. The Borrower agrees that each Participant shall be entitled to the benefits of Sections 5.03 (Increased Costs), 5.05 (Funding Losses) and 5.06 (Taxes) (subject to the requirements and limitations therein and in Article 21 (Tax Gross-Up and Indemnities) of the Common Terms Agreement, including the requirements under Section 21.5 (Status of Facility Lenders and Facility Agents) of the Common Terms Agreement (it being understood that any documentation required under Section 5.06 (Taxes) shall be delivered to the participating Lender)) to the same extent as if it were a Lender and had acquired its interest by assignment pursuant to paragraph (b) of this Section 11.04 (Assignments); provided that, such Participant (A) agrees to be subject to the provisions of Section 5.04 (Obligation to Mitigate) as if it were an assignee under paragraph (b) of this Section 11.04 (Assignments); and (B) shall not be entitled to receive any greater payment under Sections 5.03 (Increased Costs) or 5.06 (Taxes), with respect to any participation, than its participating Lender would have been entitled to receive, except to the extent such entitlement to receive a greater payment results from a Change in Law that occurs after the Participant acquired the applicable participation.

(f) Each Lender that sells a participation agrees, at such Lender’s request and expense, to use reasonable efforts to cooperate with the Borrower to effectuate the provisions of Section 5.04 (Obligation to Mitigate) with respect to any Participant. To the extent permitted by law, each Participant also shall be entitled to the benefits of Section 11.13 (Right of Set-Off) as though it were a Lender; provided that, such Participant agrees to be subject to Section 4.17 (Sharing of Payments) as though it were a Lender. Each Lender that sells a participation shall, acting solely for this purpose as a non-fiduciary agent of the Borrower, maintain a Participant Register; provided that, no Lender shall have any obligation to disclose all or any portion of the Participant Register (including the identity of any Participant or any information relating to a Participant’s interest in any commitments, loans or its other obligations under any Finance Document) to any Person except to the extent that such disclosure is necessary to establish that such commitment, loan or other obligation is in registered form under Section 5f.103-1(c) and proposed Section 1.163-5(b) of the United States Treasury Regulations (and any successor or amended versions). The entries in the Participant Register shall be conclusive absent manifest error, and such Lender shall treat each Person whose name is recorded in the Participant Register as the owner of such participation for all purposes of this Agreement notwithstanding any notice to the contrary. For the avoidance of doubt, the Credit Facility Agent (in its capacity as Credit Facility Agent) shall have no responsibility for maintaining a Participant Register.

 

65


(g) Any Lender may at any time pledge or assign a security interest in all or any portion of its rights under this Agreement (including under its Notes, if any) to secure obligations of such Lender, including any pledge or assignment to secure obligations to a Federal Reserve Bank or any central bank having jurisdiction over such Lender in accordance with any applicable law, and this Section 11.04 (Assignments) shall not apply to any such pledge or assignment of a security interest; provided that, no such pledge or assignment of a security interest shall release a Lender from any of its obligations hereunder or substitute any such pledgee or assignee for such Lender as a party hereto; provided further that, in no event shall the applicable Federal Reserve Bank, central bank, pledgee or trustee be considered to be a “Lender” or “Issuing Bank,” as applicable.

(h) The words “execution,” “signed,” “signature,” and words of like import in any Lender Assignment Agreement shall be deemed to include electronic signatures or the keeping of records in electronic form, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any applicable Government Rule, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

(i) All assignments by a Lender of all or a portion of its rights and obligations hereunder with respect to then outstanding Commitments of a certain Type shall be made only as an assignment of the same percentage of outstanding Commitments of such Type and outstanding Loans of such Type, and, in the case an assignment of rights and obligations with respect to a Working Capital Commitment, the Non-Fronting Limit under this Agreement held by such Lender. If a Working Capital Lender has no unused Working Capital Commitments, assignments of outstanding Loans owing to such Working Capital Lender may be made, together with a pro rata portion of such Working Capital Lender’s rights and obligations with respect to the Loans subject to such assignment, in such amounts, to such persons and on such terms as are permitted by and otherwise in accordance with Section 11.04(b) (Assignments).

(j) No sale, assignment, transfer, negotiation or other disposition of the interests of any Lender or Issuing Bank hereunder or under the other Finance Documents shall be allowed if it could reasonably be expected to require securities registration under any laws or regulations of any applicable jurisdiction.

(k) Notwithstanding anything to the contrary herein, (i) in no event may any Working Capital Lender assign all or any portion of its Working Capital Loans, Working Capital Commitments, LC Loans or participations in Letters of Credit to an Affiliated Lender and (ii) subject to Section 11.04(b) (Assignments) and so long as no Loan Facility Event of Default has occurred and is Continuing, any Term Lender may assign all or any portion of its Term Loans and/or Term Loan Commitments hereunder to any Affiliated Lender (pursuant to an assignment agreement in which such Affiliated Lender shall identify itself), but only if after giving effect to such assignment, Affiliated Lenders shall not, in the aggregate, own or hold Term Loans and Term Loan Commitments with an aggregate principal amount in excess of 25% of the aggregate principal amount of the Term Loans then outstanding and the remaining Term Loan Commitments (calculated as of the date of such purchase) (the “Affiliated Lender Cap”); provided that, to the

 

66


extent that any assignment to any Affiliated Lender would result in the aggregate principal amount of Term Loans and Term Loan Commitments held by Affiliated Lenders exceeding the Affiliated Lender Cap (after giving effect to any substantially simultaneous cancellation thereof), the assignment of such excess amount shall be null and void. To the extent that any Affiliated Lender holds Term Loans or Term Loan Commitments, no such Affiliated Lender shall (A) except as set forth in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, (x) have any voting or approval rights under the Finance Documents or (y) be permitted to require the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Senior Creditor to undertake any action (or refrain from taking any action) pursuant to or with respect to the Finance Documents, (B) be permitted to, in its capacity as a Lender, attend any meeting or conference call with the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Senior Creditor unless the Borrower has been invited to attend such conference calls or meetings, receive any information from the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent, any Lender or any other Senior Creditor unless such information has been made available to the Borrower (other than the right to receive notices of borrowings, notices of prepayments, and other administrative notices in respect of its Term Loans or Term Loan Commitments required to be delivered pursuant to Article II (Commitments and Advances) or Article IV (Repayments, Prepayments, Interest and Fees)) or have any rights of inspection or access relating to any Collateral Party or (C) be permitted to make or bring any claim, in its capacity as Lender, against the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Lender or Senior Creditor with respect to the duties and obligations of such Person under the Finance Documents other than in the case of a material breach by the Credit Facility Agent, the Collateral Agent, the Intercreditor Agent or any other Lender or Senior Creditor to such Affiliated Lender (except with respect to any such breaches applicable to the Lenders generally unless the other Lenders have made or brought such claims).

(l) Each Affiliated Lender, solely in its capacity as a Lender, hereby agrees, that, if any Collateral Party or any of their assets shall be subject to any voluntary or involuntary proceeding commenced under the Bankruptcy Code (“Bankruptcy Proceedings”), (i) such Affiliated Lender, solely in its capacity as a Lender, shall not take any step or action in such Bankruptcy Proceeding to object to, impede, or delay the exercise of any right or the taking of any action by the Credit Facility Agent (or the taking of any action by a third party that is supported by the Credit Facility Agent) in relation to such Affiliated Lender’s claim with respect to its Term Loans or Term Loan Commitments (an “Affiliated Lender Claim”) (including, without limitation, objecting to any debtor in possession financing, use of cash collateral, grant of adequate protection, sale or disposition, compromise, or plan of reorganization) so long as such Affiliated Lender is treated in connection with such exercise or action on the same or better terms as the other Lenders and (ii) with respect to any matter requiring the vote of Lenders during the pendency of a Bankruptcy Proceeding (including voting on any plan of reorganization), (A) the Advances held by such Affiliated Lender (and any Affiliated Lender Claim with respect thereto) shall be deemed to be voted in such Bankruptcy Proceeding in the same proportion as the allocation of voting with respect to such matter by those Lenders who are not Affiliated Lenders, so long as such Affiliated Lender is treated in connection with the exercise of such right or taking of such action on the same or better terms as the other Lenders, and (B) the Affiliated Lenders shall agree that the Credit Facility Agent shall vote on behalf of such Affiliated Lenders. For the avoidance of doubt, the Lenders and each Affiliated Lender, solely in its capacity as a Lender, agrees and acknowledge that the provisions set forth in this Section 11.04(l) (Assignments) constitute a “subordination agreement” as such term is contemplated by, and utilized in, Section 510(a) of the Bankruptcy Code, and, as such, would be enforceable for all purposes in any case where a Collateral Party has filed for protection under the Bankruptcy Code.

 

67


Section 11.05 Benefits of Agreement. Nothing in this Agreement or any other Finance Document, express or implied, shall be construed to give to any Person, other than the parties hereto, the Coordinating Lead Arranger, the Documentation Banks and each of their successors and permitted assigns under this Agreement or any other Finance Document, Participants to the extent provided in Section 11.04 (Assignments) and, to the extent expressly contemplated hereby, the Related Parties of each of the Credit Facility Agent, the Collateral Agent, the Lenders and the Issuing Banks, any benefit or any legal or equitable right or remedy under this Agreement.

Section 11.06 Counterparts; Effectiveness. This Agreement may be executed in counterparts (and by different parties hereto in different counterparts), each of which shall constitute an original, but all of which when taken together shall constitute a single contract. This Agreement shall become effective when it has been executed by the Credit Facility Agent and when the Credit Facility Agent has received counterparts hereof that, when taken together, bear the signatures of each of the other parties hereto. Delivery of an executed counterpart of a signature page of this Agreement by portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Agreement. The words “execution”, “execute”, “signed”, “signature”, and words of like import in or related to any document signed or to be signed in connection with this Agreement and the transactions contemplated hereby shall be deemed to include electronic signatures, the electronic matching of assignment terms and contract formations on electronic platforms approved by the parties hereto, or the keeping of records in electronic form, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper based recordkeeping system, as the case may be, to the extent and as provided for in any applicable law, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

Section 11.07 Indemnification by the Obligors.

(a) The Obligors, jointly and severally, hereby agree to indemnify the Credit Facility Agent, each Lender, each Issuing Bank, each Coordinating Lead Arranger, each Documentation Bank and each Related Party of any of the foregoing Persons in accordance with Section 12.18 (Other Indemnities) of the Common Security and Account Agreement and Section 2.15 (Other Indemnities) of the Intercreditor Agreement, which shall be applied mutatis mutandis to the indemnified parties under this Agreement, as well as with respect to reliance by such indemnified party on each notice purportedly given by or on behalf of the Borrower pursuant to Section 11.10 (Notices and Other Communications).

(b) To the extent that any Obligor for any reason fails to pay any amount required under Section 12.18 (Other Indemnities) of the Common Security and Account Agreement or clause (a) above to be paid by it to any of the Credit Facility Agent, any sub-agent thereof or any Related Party of any of the foregoing, each Lender severally agrees to pay to the Credit Facility Agent, any

 

68


such sub-agent, or such Related Party, as the case may be, such Lender’s ratable share (determined as of the time that the applicable unreimbursed expense or indemnity payment is sought) of such unpaid amount; provided that, the unreimbursed expense or indemnified loss, claim, damage, liability or related expense, as the case may be, was incurred by or asserted against the Credit Facility Agent or any sub-agent thereof in its capacity as such, or against any Related Party of any of the foregoing acting for the Credit Facility Agent or any sub-agent thereof in connection with such capacity. The obligations of the Lenders under this Section 11.07(b) (Indemnification by the Obligors) are subject to the provisions of Section 2.06 (Funding). The obligations of the Lenders to make payments pursuant to this Section 11.07(b) (Indemnification by the Obligors) are several and not joint and shall survive the payment in full of the Loan Obligations and the termination of this Agreement. The failure of any Lender to make payments on any date required hereunder shall not relieve any other Lender of its corresponding obligation to do so on such date, and no Lender shall be responsible for the failure of any other Lender to do so.

(c) The provisions of this Section 11.07 (Indemnification by the Obligors) shall not supersede Sections 5.03 (Increased Costs) and 5.06 (Taxes).

Section 11.08 Interest Rate Limitation. Notwithstanding anything to the contrary contained in any Finance Document, the interest paid or agreed to be paid under the Finance Documents shall not exceed the maximum rate of non-usurious interest permitted by applicable Government Rule (the “Maximum Rate”). If the Credit Facility Agent or any Lender or any Issuing Bank shall receive interest in an amount that exceeds the Maximum Rate, the excess interest shall be applied to the principal of the Loans or, if it exceeds such unpaid principal, refunded to the Borrower. In determining whether the interest contracted for, charged, or received by the Credit Facility Agent or any Lender or Issuing Bank exceeds the Maximum Rate, such Person may, to the extent permitted by applicable Government Rule, (a) characterize any payment that is not principal as an expense, fee, or premium rather than interest, (b) exclude prepayments and the effects thereof, and (c) amortize, prorate, allocate, and spread in equal or unequal parts the total amount of interest throughout the contemplated term of the Loan obligations hereunder.

Section 11.09 No Waiver; Cumulative Remedies. No failure by any Credit Facility Secured Party to exercise, and no delay by any such Person in exercising, any right, remedy, power or privilege hereunder or under any other Finance Document shall operate as a waiver thereof; nor shall any single or partial exercise of any right, remedy, power or privilege hereunder preclude any other or further exercise thereof or the exercise of any other right, remedy, power or privilege. The rights, remedies, powers and privileges herein provided, and provided under each other Finance Document, are cumulative and not exclusive of any rights, remedies, powers and privileges provided by law.

Section 11.10 Notices and Other Communications.

(a) Any communication between the parties hereto or notices provided herein to be given may be given as provided in Section 23.8 (Notices) of the Common Terms Agreement, which shall apply mutatis mutandis to this Section 11.10 (Notices and Other Communications) as if fully set forth herein except that references to the Intercreditor Agent shall be deemed references to the Credit Facility Agent as the context requires.

 

69


(b) The Credit Facility Agent, the Issuing Banks, the Collateral Agent and the Lenders shall be entitled to rely and act upon any written notices purportedly given by or on behalf of the Borrower even if (i) such notices were not made in a manner specified herein, were incomplete or were not preceded or followed by any other form of notice specified herein, or (ii) the terms thereof, as understood by the recipient, varied from any confirmation thereof. All telephonic notices to and other telephonic communications with the Credit Facility Agent, the Collateral Agent, the Issuing Banks and the Lenders by the Borrower may be recorded by the Credit Facility Agent, the Collateral Agent, the Issuing Banks and the Lenders, as applicable, and each of the parties hereto hereby consents to such recording.

(c) Notwithstanding the above, nothing herein shall prejudice the right of the Credit Facility Agent, the Collateral Agent, any of the Issuing Banks and any of the Lenders to give any notice or other communication pursuant to any Finance Document in any other manner specified in such Finance Document.

(d) Notwithstanding anything to the contrary in any other Finance Document, for so long as Natixis, New York Branch is the Credit Facility Agent, the Borrower hereby agrees that it will provide to the Credit Facility Agent all information, documents and other materials that it is obligated to furnish to the Credit Facility Agent pursuant to the Finance Documents, including all notices, requests, financial statements, financial and other reports, certificates and other information materials, but excluding any such communication that (i) relates to any Advance, (ii) relates to the payment of any principal or other amount due under this Agreement prior to the scheduled date therefor, (iii) provides notice of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default or (iv) is required to be delivered to satisfy any condition precedent to any Advance (all such non-excluded communications being referred to herein collectively as “Communications”), in an electronic/soft medium in a format acceptable to the Credit Facility Agent at the email addresses specified in Schedule Q – 2 (Addresses for Notices to Facility Agents and Facility Lenders) of the Common Terms Agreement. In addition, the Borrower agrees to continue to provide the Communications to the Credit Facility Agent in the manner specified in the Finance Documents but only to the extent requested by the Credit Facility Agent.

Section 11.11 USA Patriot Act Notice. Each of the Lenders, the Credit Facility Agent, the Collateral Agent and the Issuing Banks hereby notifies the Borrower that pursuant to the requirements of the USA Patriot Act, it is required to obtain, verify and record information that identifies the Borrower, the Guarantor and the Pledgor, which information includes the name and address of the Borrower, the Guarantor and the Pledgor and other information that will allow such Lender, the Credit Facility Agent, the Collateral Agent or such Issuing Bank, as applicable, to identify the Borrower, the Guarantor and the Pledgor in accordance with the USA Patriot Act.

Section 11.12 Payments Set Aside. To the extent that any payment by or on behalf of the Borrower is made to the Credit Facility Agent, the Collateral Agent, any Issuing Bank or any Lender, or the Credit Facility Agent, the Collateral Agent, any Issuing Bank or any Lender (as the case may be) exercises its right of setoff, and such payment or the proceeds of such setoff or any part thereof is subsequently invalidated, declared to be fraudulent or preferential, set aside or required (including pursuant to any settlement entered into by the Credit Facility Agent, the Collateral Agent, any Issuing Bank or such Lender in its discretion) to be repaid to a trustee,

 

70


receiver or any other party, in connection with any Bankruptcy Proceeding or otherwise, then (a) to the extent of such recovery, the Loan Obligation or part thereof originally intended to be satisfied by such payment shall be revived and continued in full force and effect as if such payment had not been made or such setoff had not occurred, and (b) each Lender and each Issuing Bank severally agrees to pay to the Credit Facility Agent or the Collateral Agent upon demand its applicable share (without duplication) of any amount so recovered from or repaid by the Credit Facility Agent or the Collateral Agent, as the case may be, plus interest thereon from the date of such demand to the date such payment is made at a rate per annum equal to the Federal Funds Effective Rate from time to time in effect. The obligations of the Lenders and the Issuing Banks under this Section 11.12 (Payments Set Aside) shall survive the payment in full of the Loan Obligations and the termination of this Agreement.

Section 11.13 Right of Set-Off. The provisions set forth in Section 23.2 (Right of Set-Off) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

Section 11.14 Severability. If any provision of this Agreement or any other Finance Document is held to be illegal, invalid or unenforceable, (a) the legality, validity and enforceability of the remaining provisions of this Agreement and the other Finance Documents shall not be affected or impaired thereby and (b) the parties shall endeavor in good faith negotiations to replace the illegal, invalid or unenforceable provisions with valid provisions the economic effect of which comes as close as possible to that of the illegal, invalid or unenforceable provisions. The invalidity of a provision in a particular jurisdiction shall not invalidate or render unenforceable such provision in any other jurisdiction.

Section 11.15 Survival. Notwithstanding anything in this Agreement to the contrary, Section 5.01 (Illegality), Section 5.03 (Increased Costs), Section 5.05 (Funding Losses), Section 5.06 (Taxes), Section 10.06 (Indemnification by the Lenders), Section 11.07 (Indemnification by the Obligors), Section 11.12 (Payments Set Aside) and Section 11.20 (No Recourse) shall survive any termination of this Agreement. In addition, each representation and warranty made hereunder and in any other Finance Document or other document delivered pursuant hereto or thereto or in connection herewith or therewith shall survive the execution and delivery hereof and thereof. Such representations and warranties shall be considered to have been relied upon by the Credit Facility Secured Parties regardless of any investigation made by any Credit Facility Secured Party or on their behalf and notwithstanding that the Credit Facility Secured Parties may have had notice or knowledge of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default at the time of any Advance or Loan hereunder, and shall continue in full force and effect as of the date made or any date referred to herein as long as any Loan or any other Senior Debt Obligation hereunder or under any other Finance Document shall remain unpaid or unsatisfied.

Section 11.16 Treatment of Certain Information; Confidentiality. The Credit Facility Agent, the Collateral Agent, and each of the Lenders and Issuing Banks agrees to maintain the confidentiality of the Confidential Information and all information disclosed to it concerning this Agreement and the other Finance Documents in accordance with Section 23.7 (Confidentiality) of the Common Terms Agreement.

 

71


Section 11.17 Waiver of Consequential Damages, Etc.

(a) The provisions set forth in Section 23.18 (Limitations on Liability) of the Common Terms Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

(b) No party hereto or its Related Parties shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Finance Documents or the transactions contemplated hereby or thereby.

Section 11.18 Waiver of Litigation Payments. To the extent that any party hereto may, in any action, suit or proceeding brought in any of the courts referred to in Section 11.03(b) (Applicable Government Rule; Jurisdiction, Etc. - Submission to Jurisdiction) or elsewhere arising out of or in connection with this Agreement or any other Finance Document to which it is a party, be entitled to the benefit of any provision of law requiring any other party hereto in such action, suit or proceeding to post security for the costs of such Person or to post a bond or to take similar action, each such Person hereby irrevocably waives such benefit, in each case to the fullest extent now or in the future permitted under the laws of the State of New York or, as the case may be, the jurisdiction in which such court is located.

Section 11.19 Reinstatement. This Agreement shall continue to be effective or be reinstated, as the case may be, if (and only to the extent that) any payment or performance of the obligations of the Borrower hereunder is rescinded, avoided, voidable, liable to be set aside, reduced or otherwise not properly payable to, or must otherwise be returned or restored by the Credit Facility Agent or any Lender or any Issuing Bank as a result of (a) Bankruptcy, insolvency, reorganization with respect to the Borrower or the Credit Facility Agent or any Lender or any Issuing Bank, (b) upon the dissolution of, or appointment of any intervenor, conservator, trustee or similar official for the Borrower, the Credit Facility Agent or any Lender or any Issuing Bank or for any substantial part of the Borrower’s or any other such Person’s assets, (c) as a result of any settlement or compromise with any Person (including the Borrower) in respect of such payment or otherwise, or (d) any similar event or otherwise and, in such case, the provisions of Section 10.1 (Nature of Obligations) of the Common Security and Account Agreement, which shall apply hereto mutatis mutandis.

Section 11.20 No Recourse. The provisions set forth in Section 10.3 (Limitation on Recourse) of the Common Security and Account Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

Section 11.21 Intercreditor Agreement. Any actions, consents, approvals, authorizations or discretion taken, given, made or exercised, or not taken, given, made or exercised by the Credit Facility Agent, acting as a Senior Creditor Group Representative on behalf of the Lenders and Issuing Banks, in accordance with the Intercreditor Agreement shall be binding on each Lender and Issuing Bank. Notwithstanding anything to the contrary herein, in the case of any inconsistency between this Agreement and the Intercreditor Agreement, the Intercreditor Agreement shall govern.

 

72


Section 11.22 Termination. This Agreement shall terminate and shall have no force and effect (except with respect to the provisions that expressly survive termination of this Agreement) in accordance with the provisions of Section 23.1 (Termination) of the Common Terms Agreement and if the Discharge Date with respect to the Loan Obligations has occurred.

Section 11.23 Acknowledgement and Consent to Bail-In of Affected Financial Institutions. Notwithstanding anything to the contrary in any Finance Document or in any other agreement, arrangement or understanding among any such parties, each party hereto acknowledges that any liability of any Affected Financial Institution arising under any Finance Document, to the extent such liability is unsecured, may be subject to the write-down and conversion powers of the applicable Resolution Authority and agrees and consents to, and acknowledges and agrees to be bound by:

(a) the application of any Write-Down and Conversion Powers by the applicable Resolution Authority to any such liabilities arising hereunder which may be payable to it by any party hereto that is an Affected Financial Institution; and

(b) the effects of any Bail-In Action on any such liability, including, if applicable:

(i) a reduction in full or in part or cancellation of any such liability;

(ii) a conversion of all, or a portion of, such liability into shares or other instruments of ownership in such Affected Financial Institution, its parent entity, or a bridge institution that may be issued to it or otherwise conferred on it, and that such shares or other instruments of ownership will be accepted by it in lieu of any rights with respect to any such liability under this Agreement or any other Finance Document; or

(iii) the variation of the terms of such liability in connection with the exercise of the write-down and conversion powers of the applicable Resolution Authority.

Section 11.24 Acknowledgment Regarding any Supported QFCs. To the extent that the Finance Documents provide support, through a guarantee or otherwise, for Hedging Instruments or any other agreement or instrument that is a QFC (such support “QFC Credit Support” and each such QFC a “Supported QFC”), the parties acknowledge and agree as follows with respect to the resolution power of the Federal Deposit Insurance Corporation under the Federal Deposit Insurance Act and Title II of the Dodd-Frank Wall Street Reform and Consumer Protection Act (together with the regulations promulgated thereunder, the “U.S. Special Resolution Regimes”) in respect of such Supported QFC and QFC Credit Support (with the provisions below applicable notwithstanding that the Finance Documents and any Supported QFC may in fact be stated to be governed by the laws of the State of New York and/or of the United States or any other state of the United States):

In the event a Covered Entity that is party to a Supported QFC (each, a “Covered Party”) becomes subject to a proceeding under a U.S. Special Resolution Regime, the transfer of such Supported QFC and the benefit of such QFC Credit Support (and any interest and obligation in or under such Supported QFC and such QFC Credit Support, and any rights in property securing such Supported QFC or such QFC Credit Support) from such Covered Party will be effective to the

 

73


same extent as the transfer would be effective under the U.S. Special Resolution Regime if the Supported QFC and such QFC Credit Support (and any such interest, obligation and rights in property) were governed by the laws of the United States or a state of the United States. In the event a Covered Party or a BHC Act Affiliate of a Covered Party becomes subject to a proceeding under a U.S. Special Resolution Regime, Default Rights under the Finance Documents that might otherwise apply to such Supported QFC or any QFC Credit Support that may be exercised against such Covered Party are permitted to be exercised to no greater extent than such Default Rights could be exercised under the U.S. Special Resolution Regime if the Supported QFC and the Finance Documents were governed by the laws of the United States or a state of the United States.

Section 11.25 Data Protection; Information Exchange.

(a) In compliance with the provisions of the General Data Protection Regulation (EU) 2016/679 of the European Parliament and of the European Council and the Spanish Organic Law on the Protection of Personal Data and the guarantee of digital rights, Banco Santander, S.A. (“Banco Santander”) hereby informs each other party hereto that, such party’s personal data included in this Agreement will be processed by Banco Santander for the purpose of managing the contractual relationship, and of maintaining any relationship, with such party. This processing is necessary and based on Banco Santander’s legitimate interest and on compliance with legal obligations. Such personal data will not be disclosed to third parties unless there is a legal obligation to do so and will be kept for as long as the contractual relationship remains in effect and thereafter until any liabilities arising therefrom have expired. The parties may contact the Data Protection Officer of Banco Santander at [***] and exercise their rights of access, rectification, erasure, blocking, data portability and restriction of processing (or any other recognized by law) by email to [***]. The parties hereto may also submit any claims or requests relating to the protection of personal data to the Spanish Data Protection Agency at www.aepd.es.

(b) The Obligors hereby acknowledge the disclosure to other Santander Bank group companies of the information provided in the context of the due diligence process or “Know Your Customer,” process, along with any relevant transactions-related information, that allows such companies to comply with (i) such group’s Financial Crime Compliance internal policies, (ii) such group’s legal obligations relating to the anti-money laundering and counter terrorism financing regulations and (iii) such group’s regulatory reporting to the supervisory authorities. In this regard, the Obligors hereby guarantee that the data subjects of the personal data that may be included in the referred information have been duly informed of, and when required by applicable data protection regulation, have expressly consented to, the disclosure of their personal data to that effect.

Section 11.26 Amendment and Restatement Except as expressly set forth herein, it is the intention of each of the parties hereto that:

(a) this Agreement shall not constitute a novation of the obligations and liabilities of the parties under the Original Credit Facility Agreement or the other Original Finance Documents as in effect prior to the Upsize Closing Date and all such obligations and liabilities are in all respects continued and remain outstanding as of the Upsize Closing Date (including, without limitation, all Liens and security interests in the Collateral created under the Security Documents) as provided in this Agreement;

 

74


(b) this Agreement (including all exhibits and schedules attached hereto) shall amend, restate, replace and supersede in its entirety the Original Credit Facility Agreement (including all exhibits and schedules attached thereto) on the Upsize Closing Date and the Original Credit Facility Agreement (including all Exhibits and Schedules attached thereto) thereafter shall be of no further force and effect, except (i) to evidence (A) the incurrence by the Borrower of the Borrower’s obligations, whether or not such obligations are contingent as of the Upsize Closing Date and (B) the representations and warranties made by the Borrower prior to the Upsize Closing Date (which representations and warranties shall not be superseded or rendered ineffective by this Agreement as they pertain to the period prior to the Upsize Closing Date) and (ii) with respect to the rights, privileges, immunities and indemnities of the Credit Facility Agent relating to events or circumstances arising in the period prior to the Upsize Closing Date, which shall survive;

(c) this Agreement constitutes an amendment of the Original Credit Facility Agreement made under and in accordance with the terms of Section 11.01 of the Original Credit Facility Agreement and, in connection therewith, the amendments set forth herein shall be binding upon all of the parties to the Original Credit Facility Agreement with the written consent of the Credit Facility Agent immediately prior to giving effect to this Agreement on the Upsize Closing Date;

(d) from and after the Upsize Closing Date, all references to the “Credit Facility Agreement” contained in the Finance Documents (including all exhibits, schedules, annexes and other attachments attached hereto) shall be deemed to refer to this Agreement and all references to any section (or subsection) of the “Credit Facility Agreement” in any other Finance Document shall be amended to become, mutatis mutandis, references to the corresponding provisions of this Agreement; and

(e) all Loan Obligations (as modified by this Agreement on the Upsize Closing Date) continue to be valid, enforceable and in full force and effect and not be impaired, in any respect, by the effectiveness of this Agreement.

[Remainder of page intentionally blank. Next page is signature page.]

 

75


IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by their respective officers as of the day and year first above written.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC,

as Borrower

By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title: Chief Financial Officer

VENTURE GLOBAL GATOR EXPRESS, LLC,

as Guarantor

By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title: Chief Financial Officer

 

[Signature Page to Amended and Restated Credit Facility Agreement]


Solely for purposes of Section 3.06 of the Credit Facility Agreement:

ROYAL BANK OF CANADA,

as Collateral Agent

By:   /s/ Helen Sadowski
Name: Helen Sadowski
Title: Manager, Agency

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

By:   /s/ Lisa Wong
Name: Lisa Wong
Title: Director
By:   /s/ Frederic Bouley
Name: Frederic Bouley
Title: Director

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


BANK OF AMERICA, N.A.,
as Issuing Bank, Term Lender and Working Capital Lender
By:   /s/ Ronald E. McKaig
Name: Ronald E. McKaig
Title: Managing Director

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


THE BANK OF NOVA SCOTIA, HOUSTON BRANCH, as Issuing Bank, Term Lender and Working Capital Lender
By:   /s/ Joe Lattanzi
Name: Joe Lattanzi
Title: Managing Director

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


CITY NATIONAL BANK,

an Issuing Bank

By:   /s/ Charles Hill
Name: Charles Hill
Title: SVP

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


APPLE BANK FOR SAVINGS,

as Term Lender and Working Capital Lender

By:   /s/ Dana R. MacKinnon
Name: Dana R. MacKinnon
Title: Managing Director

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


BANCO BILBAO VIZCAYA ARGENTARIA, S.A. NEW YORK BRANCH,

as Term Lender and Working Capital Lender

By:   /s/ Miguel Pena
Name: Miguel Pena
Title: Managing Director
By:   /s/ Miriam Trautmann
Name: Miriam Trautmann
Title: Managing Director

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


BANCO SANTANDER, S.A.,

as Term Lender and Working Capital Lender

By:   /s/ Benoit Felix
Name: Benoit Felix
Title: Managing Director
By:   /s/ Arturo Prieto
Name: Arturo Prieto
Title: Managing Director

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


BANK OF CHINA, NEW YORK BRANCH,

as Term Lender and Working Capital Lender

By:   /s/ Raymond Qiao
Name: Raymond Qiao
Title: Executive Vice President

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


CAIXABANK, S.A.,

as Term Lender and Working Capital Lender

By:   /s/ Helena Torres
Name: Helena Torres
Title: Structured Finance Director
By:   /s/ Maria Luisa Cobos
Name: Maria Luisa Cobos
Title: Structured Finance Director

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


CRÉDIT AGRICOLE CORPORATE AND INVESTMENT BANK,

as Term Lender and Working Capital Lender

By:   /s/ Peter Manis
Name: Peter Manis
Title: Managing Director
By:   /s/ Omer Balaban
Name: Omer Balaban
Title: Managing Director

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


DEUTSCHE BANK AG, NEW YORK BRANCH,

as Term Lender and Working Capital Lender

By:   /s/ Jeremy Eisman
Name: Jeremy Eisman
Title: Managing Director
By:   /s/ Blake Yaralian
Name: Blake Yaralian
Title: Director

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


GOLDMAN SACHS BANK USA,

as Term Lender and Working Capital Lender

By:   /s/ Robert Ehudin
Name: Robert Ehudin
Title: Authorized Signatory

 

 

[Signature Page to Amended and Restated Credit Facility Agreement]


INDUSTRIAL AND COMMERCIAL BANK OF CHINA LIMITED, NEW YORK BRANCH,

as Term Lender and Working Capital Lender

By:   /s/ Lin (Allan) Sun
Name: Lin (Allan) Sun
Title: Head of Project and Infrastructure Finance
By:   /s/ Yeqing Liu
Name: Yeqing Liu
Title: AVP

 

[Signature Page to Amended and Restated Credit Facility Agreement]


ING CAPITAL LLC,

as Term Lender and Working Capital Lender

By:   /s/ Subha Pasumarti
Name: Subha Pasumarti
Title: Managing Director
By:   /s/ Benjamin Velazquez
Name: Benjamin Velazquez
Title: Managing Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


JPMORGAN CHASE BANK, N.A.,

as Term Lender and Working Capital Lender

By:   /s/ Arina Mavilian
Name: Arina Mavilian
Title: Authorized Signatory

 

[Signature Page to Amended and Restated Credit Facility Agreement]


LANDESBANK BADEN-WURTTEMBERG, NEW YORK BRANCH,

as Term Lender and Working Capital Lender

By:   /s/ Oliver Langel
Name: Oliver Langel
Title: Executive Director
By:   /s/ Ardnt Bruns
Name: Ardnt Bruns
Title: Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


LANDESBANK HESSEN-THURINGEN GIROZENTRALE, NEW YORK BRANCH,

as Term Lender and Working Capital Lender

By:   /s/ Michael D. Novack
Name: Michael D. Novack
Title: Senior Vice President Corporate Finance
By:   /s/ Karl Strombom
Name: Karl Strombom
Title: Senior Vice President Corporate Finance

 

[Signature Page to Amended and Restated Credit Facility Agreement]


NOMURA CORPORATE FUNDING AMERICAS, LLC, as Term Lender and Working Capital Lender
By:   /s/ Vinod Mukani
Name: Vinod Mukani
Title: Managing Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


NORDDEUTSCHE LANDESBANK GIROZENTRALE, NEW YORK BRANCH,

as Term Lender and Working Capital Lender

By:   /s/ Geoffrey Mrema
Name: Geoffrey Mrema
Title: Director
By:   /s/ Cherian Thomas
Name: Cherian Thomas
Title: Senior Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


MIZUHO BANK, LTD.,

as Term Lender and Working Capital Lender

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title: Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


MUFG BANK, LTD.,

as Term Lender and Working Capital Lender

By:   /s/ Chris Lewis
Name: Chris Lewis
Title: Managing Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


NATIXIS, NEW YORK BRANCH,

as Term Lender and Working Capital Lender

By:   /s/ Amit Roy
Name: Amit Roy
Title: Managing Director
By:   /s/ Nasir Khan
Name: Nasir Khan
Title: Managing Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


REGIONS BANK,

as Term Lender and Working Capital Lender

By:   /s/ Daniel Capps
Name: Daniel Capps
Title: Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


ROYAL BANK OF CANADA,

as Term Lender and Working Capital Lender

By:   /s/ Jason S. York
Name: Jason S. York
Title: Authorized Signatory

 

[Signature Page to Amended and Restated Credit Facility Agreement]


SUMITOMO MITSUI BANKING CORPORATION,

as Term Lender and Working Capital Lender

By:

 

/s/ Paul Jun

Name:

 

Paul Jun

Title:

 

Managing Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


TRUIST BANK,

as Term Lender and Working Capital Lender

By:

 

/s/ Bryan Kunitake

Name:

 

Bryan Kunitake

Title:

 

Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


WELLS FARGO BANK, N.A.,

as Term Lender and Working Capital Lender

By:

 

/s/ Nathan Starr

Name:

 

Nathan Starr

Title:

 

Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


AOZORA BANK, LTD.,

as Term Lender

By:

 

/s/ Hirokazu Aoyama

Name:

 

Hirokazu Aoyama

Title:

 

Senior Vice President & Group Head

 

[Signature Page to Amended and Restated Credit Facility Agreement]


ASSOCIATED BANK, N.A.,

as Term Lender

By:

 

/s/ Justin Nam

Name:

 

Justin Nam

Title:

 

Senior Vice President

 

[Signature Page to Amended and Restated Credit Facility Agreement]


BANK GOSPODARSTWA KRAJOWEGO,

as Term Lender

By:

 

/s/ Sylvia Sieminske

Name:

 

Sylvia Sieminske

Title:

 

Proxy

By:

 

/s/ Usud Cluot

Name:

 

Usud Cluot

Title:

 

Proxy

 

[Signature Page to Amended and Restated Credit Facility Agreement]


BAYERISCHE LANDESBANK, NEW YORK BRANCH,

as Term Lender

By:

 

/s/ Andrew Kjoller

Name:

 

Andrew Kjoller

Title:

 

Executive Director

By:

 

/s/ Kareem Hartl

Name:

 

Kareem Hartl

Title:

 

Vice President

 

[Signature Page to Amended and Restated Credit Facility Agreement]


DZ BANK AG DEUTSCHE ZENTRAL- GENOSSENSCHAFTSBANK, NEW YORK BRANCH,

as Term Lender

By:

 

/s/ Glenn Patterson

Name:

 

Glenn Patterson

Title:

 

Director

By:

 

/s/ Zhao Liang Deng

Name:

 

Zhao Liang Deng

Title:

 

Assistant Vice President

 

[Signature Page to Amended and Restated Credit Facility Agreement]


FEDERATED HERMES PROJECT AND TRADE FINANCE TENDER FUND,

as Term Lender

By:

 

/s/ Christopher P. McGinley

Name:

 

Christopher P. McGinley

Title:

 

Vice President

 

[Signature Page to Amended and Restated Credit Facility Agreement]


FIRSTBANK PUERTO RICO D/B/A FIRSTBANK FLORIDA,

as Term Lender

By:

 

/s/ Kevin P. Flynn

Name:

 

Kevin P. Flynn

Title:

 

SVP, Corporate Banking Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


FIRST-CITIZENS BANK & TRUST COMPANY,

as Term Lender

By:

 

/s/ Stephen Norcross

Name:

 

Stephen Norcross

Title:

 

V.P.

 

[Signature Page to Amended and Restated Credit Facility Agreement]


KFW IPEX-BANK GMBH,

as Term Lender

By:

 

/s/ Andreas Portner

Name:

 

Andreas Portner

Title:

 

Director

By:

 

/s/ Carsten Kreckel

Name:

 

Carsten Kreckel

Title:

 

Vice President

 

[Signature Page to Amended and Restated Credit Facility Agreement]


THE KOREA DEVELOPMENT BANK,

as Term Lender

By:

 

/s/ Ahn Wook Sang

Name:

 

Ahn Wook Sang

Title:

  General Manager, Project Finance Department II, Korea Development Bank

 

[Signature Page to Amended and Restated Credit Facility Agreement]


NATIONAL BANK OF CANADA,

as Term Lender

By:

 

/s/ John Hunt

Name:

 

John Hunt

Title:

 

Authorized Signatory

By:

 

/s/ Mark Williamson

Name:

 

Mark Williamson

Title:

 

Authorized Signatory

 

[Signature Page to Amended and Restated Credit Facility Agreement]


NONGHYUP BANK HONG KONG BRANCH,

as Term Lender

By:

 

/s/ You, Yong Jae

Name:

 

You, Yong Jae

Title:

 

General Manager

 

[Signature Page to Amended and Restated Credit Facility Agreement]


PROJECT AND TRADE FINANCE CORE FUND,

as Term Lender

By:

 

/s/ Christopher McGinley

Name:

 

Christopher McGinley

Title:

 

Vice President

 

[Signature Page to Amended and Restated Credit Facility Agreement]


RAYMOND JAMES BANK,

as Term Lender

By:

 

/s/ Robert F. Moyle

Name:

 

Robert F. Moyle

Title:

 

Managing Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


BANCO DE SABADELL, S.A., MIAMI BRANCH,

as Term Lender

By:

 

/s/ Enrique Castillo

Name:

 

Enrique Castillo

Title:

 

Head of Corporate Banking

By:

 

/s/ Maurici Llado

Name:

 

Maurici Llado

Title:

 

Managing Director

 

[Signature Page to Amended and Restated Credit Facility Agreement]


SHINHAN BANK NEW YORK BRANCH,

as Term Lender

By:

 

/s/ Jun Ho Lee

Name:

 

Jun Ho Lee

Title:

 

Deputy General Manager

 

[Signature Page to Amended and Restated Credit Facility Agreement]


SCHEDULE I TO

CREDIT FACILITY AGREEMENT

Lenders, Commitments

Term Loan Commitments1

 

Term Lenders

   Initial Base
Term Loan
Commitment
     Incremental
Base Term
Loan
Commitment
     Aggregate
Base Term
Loan
Commitment
     Initial
Contingency
Reserve

Term Loan
Commitment
     Incremental
Contingency
Reserve

Term Loan
Commitment
     Aggregate
Contingency
Reserve

Term Loan
Commitment
     Aggregate
Term Loan
Commitments
 

Bank of America, N.A.

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Goldman Sachs Bank USA

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Mizuho Bank, Ltd.

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Banco Santander, S.A.

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Bank of China, New York Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

CaixaBank, S.A.

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Deutsche Bank AG, New York Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Industrial and Commercial Bank of China Limited, New York Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

ING Capital LLC

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

 

1 

Term Loan Commitments have been rounded to the nearest cent for purposes of display on this Schedule I.


Term Lenders

   Initial Base
Term Loan
Commitment
     Incremental
Base Term
Loan
Commitment
     Aggregate
Base Term
Loan
Commitment
     Initial
Contingency
Reserve

Term Loan
Commitment
     Incremental
Contingency
Reserve

Term Loan
Commitment
     Aggregate
Contingency
Reserve

Term Loan
Commitment
     Aggregate
Term Loan
Commitments
 

JPMorgan Chase Bank, N.A.

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Landesbank Baden – Württemberg, New

York Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

MUFG Bank, Ltd.

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Natixis, New York Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Nomura Corporate Funding Americas, LLC

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Royal Bank of Canada

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Sumitomo Mitsui Banking Corporation

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

The Bank of Nova Scotia, Houston

Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Truist Bank

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

The Korea Development Bank

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

FirstBank Puerto Rico d/b/a FirstBank

Florida

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Bayerische Landesbank, New

York Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  


Term Lenders

   Initial Base
Term Loan
Commitment
     Incremental
Base Term
Loan
Commitment
     Aggregate
Base Term
Loan
Commitment
     Initial
Contingency
Reserve

Term Loan
Commitment
     Incremental
Contingency
Reserve

Term Loan
Commitment
     Aggregate
Contingency
Reserve

Term Loan
Commitment
     Aggregate
Term Loan
Commitments
 

Associated Bank, N.A.

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Banco Bilbao Vizcaya Argentaria, S.A. New

York Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

KFW IPEX-Bank

GmbH

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Raymond James Bank

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

First-Citizens Bank & Trust Company

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Landesbank Hessen- Thuringen Girozentrale, New York Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Shinhan Bank New York Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Banco de Sabadell, S.A., Miami Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Regions Bank

     $[***]        $[***]        $[***]        $[***]        $[***]        [***]        $[***]  

DZ Bank AG, Deutsche Zentral-

Genossenschaftsbank, New York Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Aozora Bank, Ltd.

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Norddeutsche Landesbank

Girozentrale, New York Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  


Term Lenders

   Initial Base
Term Loan
Commitment
     Incremental
Base Term
Loan
Commitment
     Aggregate
Base Term
Loan
Commitment
     Initial
Contingency
Reserve

Term Loan
Commitment
     Incremental
Contingency
Reserve

Term Loan
Commitment
     Aggregate
Contingency
Reserve

Term Loan
Commitment
     Aggregate
Term Loan
Commitments
 

Crédit Agricole Corporate and Investment Bank

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Bank Gospodarstwa Krajowego

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Nonghyup Bank Hong Kong Branch

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Federated Hermes Project and Trade

Finance Tender Fund

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Project and Trade Finance Core Fund

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

National Bank of Canada

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Apple Bank for Savings

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  

Wells Fargo Bank, N.A.

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $[***]  
                    

 

 

 

Total

     $[***]        $[***]        $[***]        $[***]        $[***]        $[***]        $12,948,145,243.33  
                    

 

 

 

Working Capital Commitments2

 

Working Capital Lenders

   Initial
Working
Capital
Commitment
     Incremental
Working
Capital
Commitment
     Aggregate
Working
Capital
Commitment
 

Bank of America, N.A.

     $[***]        $[***]        $[***]  

 

2 

Working Capital Commitments have been rounded to the nearest cent for purposes of display on this Schedule I.


Working Capital Lenders

  Initial
Working
Capital
Commitment
       Incremental
Working
Capital
Commitment
       Aggregate
Working
Capital
Commitment
 

Goldman Sachs Bank USA

    $[***]          $[***]          $[***]  

Mizuho Bank, Ltd.

    $[***]          $[***]          $[***]  

Banco Santander, S.A.

    $[***]          $[***]          $[***]  

Bank of China, New York Branch

    $[***]          $[***]          $[***]  

CaixaBank, S.A.

    $[***]          $[***]          $[***]  

Deutsche Bank AG, New York Branch

    $[***]          $[***]          $[***]  

Industrial and Commercial Bank of China Limited, New York Branch

    $[***]          $[***]          $[***]  

ING Capital LLC

    $[***]          $[***]          $[***]  

JPMorgan Chase Bank, N.A.

    $[***]          $[***]          $[***]  

Landesbank Baden-Württemberg, New York Branch

    $[***]          $[***]          $[***]  

MUFG Bank, Ltd.

    $[***]          $[***]          $[***]  

Natixis, New York Branch

    $[***]          $[***]          $[***]  

Nomura Corporate Funding Americas, LLC

    $[***]          $[***]          $[***]  

Royal Bank of Canada

    $[***]          $[***]          $[***]  

Sumitomo Mitsui Banking Corporation

    $[***]          $[***]          $[***]  

The Bank of Nova Scotia, Houston Branch

    $[***]          $[***]          $[***]  

Truist Bank

    $[***]          $[***]          $[***]  

Banco Bilbao Vizcaya Argentaria, S.A. New York Branch

    $[***]          $[***]          $[***]  

Landesbank Hessen-Thuringen Girozentrale, New York Branch

    $[***]          $[***]          $[***]  

Regions Bank

    $[***]          $[***]          $[***]  


Working Capital Lenders

   Initial
Working
Capital
Commitment
     Incremental
Working
Capital
Commitment
     Aggregate
Working
Capital
Commitment
 

Norddeutsche Landesbank Girozentrale, New York Branch

     $[***]        $[***]        $[***]  

Credit Agricole Corporate and Investment Bank

     $[***]        $[***]        $[***]  

Apple Bank for Savings

     $[***]        $[***]        $[***]  

Wells Fargo Bank, N.A.

     $[***]        $[***]        $[***]  

Total

     $[***]        $[***]        $2,100,000,000.00  


SCHEDULE II

TO CREDIT FACILITY AGREEMENT

Issuing Bank Limits3

 

Issuing Bank

   Initial
Fronting
Limit
    Incremental
Fronting
Limit
     Aggregate
Fronting
Limit
     Initial
Non-

Fronting
Limit
     Incremental
Non-Fronting
Limit
     Aggregate
Non-Fronting
Limit
     Initial
Issuing
Bank
Limit
     Incremental
Issuing
Bank Limit
     Aggregate
Issuing Bank
Limit
 

Bank of America, N.A.

   $ [***]       [***]      $ [***]        [***]        [***]        [***]      $ [***]        [***]      $ 200,000,000  

The Bank of Nova Scotia, Houston Branch

   $ [***]       [***]      $ [***]        [***]        [***]        [***]      $ [***]        [***]      $ 200,000,000  

City National Bank4

   $ [***] 5      [***]      $ [***]        [***]        [***]        [***]      $ [***]        [***]      $ 43,859,380  

 

3 

For the avoidance of doubt, in accordance with Section 3.01(b) (Letters of Credit) of the Credit Facility Agreement, no Issuing Bank shall be required to issue any Letter of Credit or any amendment to increase the face or stated amount of any Letter of Credit if, after such issuance or amendment, the aggregate Working Capital Commitment Exposure for all Working Capital Lenders shall exceed the Aggregate Working Capital Commitments, among the other terms and conditions set forth in the Credit Facility Agreement.

4 

Issuing Bank solely in respect of Existing Letters of Credit issued by City National Bank on or before the Initial Closing Date.

5 

Aggregate amount of Existing Letters of Credit issued by City National Bank on or before the Initial Closing Date.


SCHEDULE III TO

CREDIT FACILITY AGREEMENT

Amortization Schedule

[Omitted]


SCHEDULE IV TO

CREDIT FACILITY AGREEMENT

Credit Facility Agent Account Details

 

To:    [***]
ABA:    [***]
Account Name:    [***]
Account Number:    [***]
Reference:    [***]


SCHEDULE V TO

CREDIT FACILITY AGREEMENT

Existing Letters of Credit

[Omitted]


EXHIBIT A TO

CREDIT FACILITY AGREEMENT

Definitions

Advance” means, as context requires, a Term Loan Advance, a Working Capital Advance, or both.

Advance Date” means, with respect to each Advance, the date on which funds are disbursed by the Lenders (or the Credit Facility Agent on their behalf) to the Borrower.

Affected Financial Institution” means (a) any EEA Financial Institution or (b) any UK Financial Institution.

Affiliated Lender” means Sponsor or any of its Affiliates.

Affiliated Lender Cap” has the meaning specified in Section 11.04(k) (Assignments).

Affiliated Lender Claim” has the meaning specified in Section 11.04(l) (Assignments).

Aggregate Commitments” means, as context requires, the sum of the Term Loan Commitments or the sum of the Working Capital Commitments.

Aggregate Term Loan Commitments” means the sum of the Term Loan Commitments.

Aggregate Working Capital Commitments” means the sum of the Working Capital Commitments.

Agreement” has the meaning provided in the preamble.

Amortization Schedule” means, as context requires, the Initial Amortization Schedule or the Upsize Amortization Schedule or both.

Applicable Margin” means for each type of Loan (and, in respect of SOFR Loans, with the applicable Interest Period) identified below during each applicable period set forth in the table shown below, the applicable per annum percentage under the relevant column heading below:

 

Applicable Period

   Base Rate
Loans
    One-Month
SOFR

Loans
    Three-Month
SOFR Loans
   

Six-Month
SOFR Loans

From the Initial Closing Date until the third (3rd) anniversary of the Initial Closing Date

     0.875     1.975     2.025   2.125%

From the third (3rd) anniversary of the Initial Closing Date until the fifth (5th) anniversary of the Initial Closing Date

     1.125     2.225     2.275   2.375%

From the fifth (5th) anniversary of the Initial Closing Date until the Final Maturity Date

     1.375     2.475     2.525   2.625%

 

1


Availability Period” means, as context requires, the Term Loan Availability Period or the Working Capital Loan Availability Period.

Available Tenor” means, as of any date of determination and with respect to the then- current Benchmark, as applicable, (a) if such Benchmark is a term rate, any tenor for such Benchmark (or component thereof) that is or may be used for determining the length of an interest period pursuant to this Agreement or (b) otherwise, any payment period for interest calculated with reference to such Benchmark (or component thereof) that is or may be used for determining any frequency of making payments of interest calculated with reference to such Benchmark pursuant to this Agreement, in each case, as of such date and not including, for the avoidance of doubt, any tenor for such Benchmark that is then-removed from the definition of “Interest Period” pursuant to Section 5.07(d) (Replacement Benchmark Setting - Unavailability of Tenor of Benchmark).

Bail-In Action” means the exercise of any Write-Down and Conversion Powers by the applicable Resolution Authority in respect of any liability of an Affected Financial Institution.

Bail-In Legislation” means, (a) with respect to any EEA Member Country implementing Article 55 of Directive 2014/59/EU of the European Parliament and of the Council of the European Union, the implementing law, regulation or requirement for such EEA Member Country from time to time which is described in the EU Bail-In Legislation Schedule and (b) with respect to the United Kingdom, Part I of the United Kingdom Banking Act 2009 (as amended from time to time) and any other law, regulation or rule applicable in the United Kingdom relating to the resolution of unsound or failing banks, investment firms or other financial institutions or their affiliates (other than through liquidation, administration or other insolvency proceedings).

Bankruptcy Proceeding” has the meaning set forth in Section 11.04(l) (Assignments).

Base Rate” means, for any day, a fluctuating rate per annum equal to the highest of (a) the Federal Funds Effective Rate plus 0.50%, (b) the prime rate published in The Wall Street Journal for such day; provided that, if The Wall Street Journal ceases to publish for any reason such rate of interest, “Base Rate” shall mean the prime lending rate as set forth on the Bloomberg page PRIMBB Index (or successor page) for such day (or such other service as determined by the Credit Facility Agent from time to time for purposes of providing quotations of prime lending interest rates) and (c) Term SOFR for an interest period of one month plus 1.10%; provided that, for purposes of this Agreement, if the Base Rate for any interest period is less than zero percent (0%), it shall be deemed zero percent (0%) for such interest period.

 

2


Base Rate Loan” means any Loan bearing interest at a rate determined by reference to the Base Rate and the provisions of Article II (Commitments and Advance) and Article IV (Repayments, Prepayments, Interest and Fees).

Base Rate Term SOFR Determination Day” has the meaning provided in the definition of “Term SOFR.”

Base Term Loan Commitment” means the Initial Base Term Loan Commitment and the Incremental Base Term Loan Commitment of any Term Lender or if any Term Lender has entered into one or more Lender Assignment Agreements, such amount as set forth opposite the name of such Term Lender and any assignor Term Lender in the Register maintained by the Credit Facility Agent pursuant to Section 2.06(f) (Funding), as the same may be increased in accordance with Section 2.01 (Term Loans) or as the same may be reduced in accordance with Section 2.07 (Termination or Reduction of Commitments), and “Base Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

Benchmark” means, initially, the Term SOFR Reference Rate; provided that, if a Benchmark Transition Event has occurred with respect to the Term SOFR Reference Rate or the then-current Benchmark, then “Benchmark” means the applicable Benchmark Replacement to the extent that such Benchmark Replacement has replaced such prior benchmark rate pursuant to Section 5.07(a) (Replacement Benchmark Setting – Benchmark Replacement).

Benchmark Replacement” means, with respect to any Benchmark Transition Event, the sum of: (a) the alternate benchmark rate that has been selected by the Credit Facility Agent and the Borrower giving due consideration to (i) any selection or recommendation of a replacement benchmark rate or the mechanism for determining such a rate by the Relevant Governmental Body or (ii) any evolving or then-prevailing market convention for determining a benchmark rate as a replacement to the then-current Benchmark for Dollar-denominated syndicated credit facilities at such time and (b) the related Benchmark Replacement Adjustment; provided that, if such Benchmark Replacement as so determined would be less than the Floor, such Benchmark Replacement will be deemed to be the Floor for the purposes of this Agreement and the other applicable Finance Documents.

Benchmark Replacement Adjustment” means, with respect to any replacement of the then- current Benchmark with an Unadjusted Benchmark Replacement, the spread adjustment, or method for calculating or determining such spread adjustment, (which may be a positive or negative value or zero) that has been selected by the Credit Facility Agent and the Borrower giving due consideration to (a) any selection or recommendation of a spread adjustment, or method for calculating or determining such spread adjustment, for the replacement of such Benchmark with the applicable Unadjusted Benchmark Replacement by the Relevant Governmental Body or (b) any evolving or then-prevailing market convention for determining a spread adjustment, or method for calculating or determining such spread adjustment, for the replacement of such Benchmark with the applicable Unadjusted Benchmark Replacement for Dollar-denominated syndicated credit facilities at such time.

 

3


Benchmark Replacement Date” means the earliest to occur of the following events with respect to the then-current Benchmark:

(a) in the case of clause (a) or (b) of the definition of “Benchmark Transition Event,” the later of (i) the date of the public statement or publication of information referenced therein and (ii) the date on which the administrator of such Benchmark (or the published component used in the calculation thereof) permanently or indefinitely ceases to provide all Available Tenors of such Benchmark (or such component thereof); or

(b) in the case of clause (c) of the definition of “Benchmark Transition Event,” the first date on which such Benchmark (or the published component used in the calculation thereof) has been determined and announced by or on behalf of the administrator of such Benchmark (or such component thereof) or the regulatory supervisor for the administrator of such Benchmark (or such component thereof) to be non-representative or non-compliant with or non-aligned with the International Organization of Securities Commissions (IOSCO) Principles for Financial Benchmarks; provided that such non-representativeness, non-compliance or non-alignment will be determined by reference to the most recent statement or publication referenced in such clause (c) and even if any Available Tenor of such Benchmark (or such component thereof) continues to be provided on such date.

For the avoidance of doubt, the “Benchmark Replacement Date” will be deemed to have occurred in the case of clause (a) or (b) with respect to any Benchmark upon the occurrence of the applicable event or events set forth therein with respect to all then-current Available Tenors of such Benchmark (or the published component used in the calculation thereof).

Benchmark Transition Event” means the occurrence of one or more of the following events with respect to the then-current Benchmark:

(a) a public statement or publication of information by or on behalf of the administrator of such Benchmark (or the published component used in the calculation thereof) announcing that such administrator has ceased or will cease to provide all Available Tenors of such Benchmark (or such component thereof), permanently or indefinitely; provided that, at the time of such statement or publication, there is no successor administrator that will continue to provide any Available Tenor of such Benchmark (or such component thereof);

(b) a public statement or publication of information by the regulatory supervisor for the administrator of such Benchmark (or the published component used in the calculation thereof), the Federal Reserve Board, the Federal Reserve Bank of New York, an insolvency official with jurisdiction over the administrator for such Benchmark (or such component), a resolution authority with jurisdiction over the administrator for such Benchmark (or such component) or a court or an entity with similar insolvency or resolution authority over the administrator for such Benchmark (or such component), which states that the administrator of such Benchmark (or such component) has ceased or will cease to provide all Available Tenors of such Benchmark (or such component thereof) permanently or indefinitely; provided that, at the time of such statement or publication, there is no successor administrator that will continue to provide any Available Tenor of such Benchmark (or such component thereof); or

 

4


(c) a public statement or publication of information by or on behalf of the administrator of such Benchmark (or the published component used in the calculation thereof) or the regulatory supervisor for the administrator of such Benchmark (or the published component used in the calculation thereof) announcing that all Available Tenors of such Benchmark (or such component thereof) are not, or as of a specified future date, will not be, representative or in compliance with or aligned with the International Organization of Securities Commissions (IOSCO) Principles for Financial Benchmarks.

For the avoidance of doubt, a “Benchmark Transition Event” will be deemed to have occurred with respect to any Benchmark if a public statement or publication of information set forth above has occurred with respect to each then-current Available Tenor of such Benchmark (or the published component used in the calculation thereof)

Benchmark Transition Start Date” means, in the case of a Benchmark Transition Event, the earlier of (a) the applicable Benchmark Replacement Date and (b) if such Benchmark Transition Event is a public statement or publication of information of a prospective event, the 90th day prior to the expected date of such event as of such public statement or publication of information (or if the expected date of such prospective event is fewer than 90 days after such statement or publication, the date of such statement or publication).

Benchmark Unavailability Period” means, the period (if any) (a) beginning at the time that a Benchmark Replacement Date has occurred if, at such time, no Benchmark Replacement has replaced the then-current Benchmark for all purposes hereunder and under any Finance Document in accordance with Section 5.07 (Replacement Benchmark Setting) and (b) ending at the time that a Benchmark Replacement has replaced the then-current Benchmark for all purposes hereunder and under any Finance Document in accordance with Section 5.07 (Replacement Benchmark Setting).

Benefit Plan” means any of (a) any “employee benefit plan” (as defined in ERISA) that is subject to Title I of ERISA, (b) a “plan” as defined in and subject to Section 4975 of the Code or (c) any Person whose assets include (for purposes of ERISA Section 3(42) or otherwise for purposes of Title I of ERISA or Section 4975 of the Code) the assets of any such “employee benefit plan” or “plan”.

BHC Act Affiliate” of a party means an “affiliate” (as such term is defined under, and interpreted in accordance with, 12 U.S.C. 1841(k)) of such party.

Commitment” means, as context requires, a Term Loan Commitment, a Working Capital Commitment or both.

 

5


Commitment Fee Rate” means, during each applicable period set forth in the table shown below, the applicable per annum percentage below:

 

Applicable Period

  

Commitment
Fee Rate

From the Initial Closing Date until the third (3rd) anniversary of the Initial Closing Date

   0.65625%

From the third (3rd) anniversary of the Initial Closing Date until the fifth (5th) anniversary of the Initial Closing Date

   0.74375%

From the fifth (5th) anniversary of the Initial Closing Date until the Final Maturity Date

   0.83125%

Commitment Fees” has the meaning provided in Section 4.15(b) (Fees).

Commitment Percentage” means (a) as to any Working Capital Lender at any time, the percentage that such Working Capital Lender’s Working Capital Commitment less its Working Capital Commitment Exposure then constitutes of the Aggregate Working Capital Commitment less the total Working Capital Commitment Exposure of all Working Capital Lenders, (b) as to any Term Lender at any time, the percentage that such Term Lender’s Term Loan Commitment constitutes of the Aggregate Term Loan Commitment, and (c) as to any Issuing Bank at any time, the percentage that such Issuing Bank’s Issuing Bank Limit less the available balance of Letters of Credit issued by such Issuing Bank then constitutes of the aggregate Issuing Bank Limits for all Issuing Banks less the total available balance of Letters of Credit issued by all Issuing Banks.

Communications” has the meaning provided in Section 11.10(d) (Notices and Other Communications).

Conforming Changes” means, with respect to either the use or administration of Term SOFR or the use, administration, adoption or implementation of any Benchmark Replacement, any technical, administrative or operational changes (including changes to the definition of “Base Rate,” the definition of “Business Day,” the definition of “U.S. Government Securities Business Day,” the definition of “Interest Period” or any similar or analogous definition (or the addition of a concept of “interest period”), timing and frequency of determining rates and making payments of interest, timing of borrowing requests or prepayment, conversion or continuation notices, the applicability and length of lookback periods, the applicability of Section 5.05 (Funding Losses) and other technical, administrative or operational matters) that the Credit Facility Agent decides may be appropriate to reflect the adoption and implementation of any such rate or to permit the use and administration thereof by the Credit Facility Agent in a manner substantially consistent with market practice (or, if the Credit Facility Agent decides that adoption of any portion of such market practice is not administratively feasible or if the Credit Facility Agent determines that no market practice for the administration of any such rate exists, in such other manner of administration as the Credit Facility Agent decides is reasonably necessary in connection with the administration of this Agreement and the other Finance Documents).

 

6


Contingency Reserve Term Loan Commitment” means the Initial Contingency Reserve Term Loan Commitment and the Incremental Contingency Reserve Term Loan Commitment of any Term Lender or if any Term Lender has entered into one or more Lender Assignment Agreements, such amount as set forth opposite the name of such Term Lender and any assignor Term Lender in the Register maintained by the Credit Facility Agent pursuant to Section 2.06(f) (Funding), as the same may be reduced in accordance with Section 2.01 (Term Loans) or Section 2.07 (Termination or Reduction of Commitments), and “Contingency Reserve Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

Coordinating Lead Arrangers” means the Initial Coordinating Lead Arrangers and the Upsize Coordinating Lead Arrangers.

Covered Entity” means any of the following:

(a) a “covered entity” as that term is defined in, and interpreted in accordance with, 12 C.F.R. § 252.82(b);

(b) a “covered bank” as that term is defined in, and interpreted in accordance with, 12 C.F.R. § 47.3(b); or

(c) a “covered FSI” as that term is defined in, and interpreted in accordance with, 12 C.F.R. § 382.2(b).

Covered Party” has the meaning provided in Section 11.24 (Acknowledgment Regarding any Supported QFCs).

Credit Facility Agent” has the meaning provided in the preamble.

Credit Facility Secured Parties” means the Lenders, the Issuing Banks, the Credit Facility Agent, the Collateral Agent and each of their respective successors and permitted assigns, in each case in connection with the Credit Facility Agreement.

Default Right” has the meaning assigned to that term in, and shall be interpreted in accordance with, 12 C.F.R. §§ 252.81, 47.2 or 382.1, as applicable.

Defaulting Lender” means a Lender which (a) has defaulted in its obligations to fund all or any portion of any Term Loan or otherwise failed to comply with its obligations under Section 2.01 (Term Loans), Section 2.03 (Working Capital Loans), Section 2.06 (Funding) or Section 3.02 (Reimbursement to Issuing Banks), unless (i) such default or failure is no longer continuing or has been cured within three (3) Business Days after such default or failure or (ii) such Lender notifies the Credit Facility Agent and the Borrower in writing that such failure is the result of such Lender’s good faith determination that one or more conditions precedent to funding (each of which conditions precedent, together with any applicable default, shall be specifically identified in such writing) has not been satisfied, (b) has notified the Borrower and/or the Credit Facility Agent that it does not intend to comply with its obligations under Section 2.01 (Term Loans), Section 2.03 (Working Capital Loans), Section 2.06 (Funding) or Section 3.02 (Reimbursement to Issuing Banks) or has made a public statement to that effect, unless such Lender notifies the Credit Facility Agent and the Borrower in writing that such intention is the result of such Lender’s good faith determination that one or more conditions precedent to funding (each of which conditions precedent, together with any applicable default, shall be specifically identified in such writing) has not been

 

7


satisfied, (c) has failed, within three (3) Business Days, after written request by the Credit Facility Agent or the Borrower, to confirm in writing to the Credit Facility Agent and the Borrower that it will comply with its prospective funding obligations under Section 2.03 (Working Capital Loans), Section 2.06 (Funding) or Section 3.02 (Reimbursement to Issuing Banks) (provided that such Lender shall cease to be a Defaulting Lender pursuant to this clause (c) upon receipt of such written confirmation by the Credit Facility Agent and the Borrower), (d) has, or has a direct or indirect parent company that has, other than via Undisclosed Administration, (i) become the subject of a Bankruptcy Proceeding, or (ii) had appointed for it a receiver, custodian, conservator, trustee, administrator, assignee for the benefit of creditors or similar Person charged with reorganization or liquidation of its business or assets, including the Federal Deposit Insurance Corporation or any other state or federal regulatory authority acting in such a capacity or (e) has become the subject of a Bail-In Action; provided that, for the avoidance of doubt, a Lender shall not be a Defaulting Lender solely by virtue of (i) the ownership or acquisition of any equity interest in that Lender or any direct or indirect parent company thereof by a Governmental Authority or (ii) in the case of a solvent Person, the precautionary appointment of an administrator, guardian, custodian or other similar official by a Governmental Authority under or based on the law of the country where such Person is subject to home jurisdiction supervision if Government Rule requires that such appointment not be publicly disclosed; in each case, where such action does not result in or provide such Lender with immunity from the jurisdiction of courts within the United States or from the enforcement of judgments or writs of attachment on its assets or permit such Lender (or such Governmental Authority) to reject, repudiate, disavow or disaffirm any contracts or agreements made with such Lender. Any determination by the Credit Facility Agent that a Lender is a Defaulting Lender under any one or more of the clauses above shall be conclusive and binding absent manifest error, and such Lender shall be deemed to be a Defaulting Lender upon delivery of written notice of such determination to the Borrower and each Lender.

Documentation Bank” means the Initial Documentation Banks and the Upsize Documentation Banks.

EEA Financial Institution” means (a) any credit institution or investment firm established in any EEA Member Country which is subject to the supervision of an EEA Resolution Authority, (b) any entity established in an EEA Member Country which is a parent of an institution de-scribed in clause (a) of this definition, or (c) any financial institution established in an EEA Member Country which is a subsidiary of an institution described in clauses (a) or (b) of this definition and is subject to consolidated supervision with its parent.

EEA Member Country” means any of the member states of the European Union, Iceland, Liechtenstein, and Norway.

EEA Resolution Authority” means any public administrative authority or any Person entrusted with public administrative authority of any EEA Member Country (including any delegee) having responsibility for the resolution of any EEA Financial Institution.

Eligible Assignee” means (a) an existing Lender, (b) any Affiliate of a Lender, (c) any Approved Fund with respect to a Lender or (d) any commercial bank, insurance company, investment or mutual fund or other entity that is an “accredited investor” (as defined in Regulation D under the Securities Act) and which extends credit or buys loans (excluding in each such case any Disqualified

 

8


Institution or any Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof); provided that, for any assignment, novation or transfer during the Term Loan Availability Period (or in the event of an assignment of a Working Capital Commitment, the Working Capital Loan Availability Period) made in reliance on clause (b) or (c) above, such Lender or its rated Affiliate shall have agreed in writing with the Borrower to remain obligated to promptly fund any duly requested disbursement of the Commitment assigned, novated or transferred to such assignee or transferee (or any part thereof) should such assignee or transferee default in its obligation to fund any portion of the Commitment assigned or transferred to it.

Erroneous Payment” has the meaning assigned to it in Section 10.15(a) (Erroneous Payments).

Erroneous Payment Deficiency Assignment” has the meaning assigned to it in Section 10.15(d)(i) (Erroneous Payments).

Erroneous Payment Impacted Class” has the meaning assigned to it in Section 10.15(d)(i) (Erroneous Payments).

Erroneous Payment Return Deficiency” has the meaning assigned to it in Section 10.15(d)(i) (Erroneous Payments).

Erroneous Payment Subrogation Rights” has the meaning assigned to it in Section 10.15(e) (Erroneous Payments).

EU Bail-In Legislation Schedule” means the EU Bail-In Legislation Schedule published by the Loan Market Association (or any successor Person), as in effect from time to time.

Existing Letters of Credit” means the letters of credit described in Schedule V (Existing Letters of Credit). Each Existing Letter of Credit shall be a Fronted Letter of Credit.

Federal Funds Effective Rate” means, for any day, the rate calculated by the Federal Reserve Bank of New York based on such day’s federal funds transactions by depositary institutions, as determined in such manner as shall be set forth on the Federal Reserve Bank of New York’s Website from time to time, and published on the next succeeding Business Day by the Federal Reserve Bank of New York as the federal funds effective rate. If the Federal Funds Effective Rate as so determined would be less than zero, such rate shall be deemed to be zero for the purposes of this Agreement.

Federal Reserve Board” means the Board of Governors of the Federal Reserve System of the United States.

Fees” means, collectively, each of the fees payable by the Borrower for the account of any Lender, any Issuing Bank or the Credit Facility Agent pursuant to Section 4.15 (Fees).

Final Maturity Date” means May 25, 2029.

 

9


First Repayment Date” has the meaning provided in Section 4.01(d) (Repayment of Term Loan Advances).

First Upsize Repayment Date” has the meaning provided in Section 4.01(e) (Repayment of Term Loan Advances).

Floor” means a rate of interest equal to 0.0%.

Fronted Letter of Credit” means a Letter of Credit other than a Non-Fronted Letter of Credit.

Fronting Exposure” means, at any time there is a Defaulting Lender, with respect to any

Issuing Bank, such Defaulting Lender’s pro rata share of outstanding LC Exposure with respect to Letters of Credit issued by such Issuing Bank, other than LC Exposure as to which such Defaulting Lender’s participation obligation has been reallocated to other Working Capital Lenders or cash collateralized in accordance with the terms hereof.

Fronting Fee” has the meaning provided in Section 4.15(d) (Fees).

Fronting Limit” means, at any time, with respect to any Issuing Bank, the aggregate amount of its Initial Fronting Limit and Incremental Fronting Limit, or, in the case of any Working Capital Lender that becomes an Issuing Bank hereunder pursuant to Section 3.05 (Resignation as an Issuing Bank) or otherwise, such amount as set forth in the agreement evidencing the appointment of such Working Capital Lender as an Issuing Bank.

Guarantee” means the guarantee issued pursuant to the Common Security and Account Agreement by the Guarantor. The terms “Guarantee” and “Guaranteed” used as verbs shall have correlative meanings.

Illegality Notice” has the meaning provided in Section 5.01 (Illegality).

Incremental Amendment” has the meaning given in Section 2.08(c) (Incremental Commitments).

Incremental Base Term Loan Commitment” means the incremental commitment of a Term Lender to make or otherwise fund a Term Loan pursuant to Section 2.01(a)(i) (Term Loans), as set forth opposite the name of such Term Lender in the column entitled “Incremental Base Term Loan Commitment” in Schedule I (Lenders, Commitments), and “Incremental Base Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

Incremental Commitment” means, as context requires, an Incremental Term Loan Commitment, an Incremental Working Capital Commitment or both.

Incremental Contingency Reserve Term Loan Commitment” means the incremental commitment of a Term Lender to make or otherwise fund a Term Loan pursuant to Section 2.01(a)(ii) (Term Loans), as set forth opposite the name of such Term Lender in the column entitled “Incremental Contingency Reserve Term Loan Commitment” in Schedule I (Lenders, Commitments), and “Incremental Contingency Reserve Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

 

10


Incremental Fronting Limit” means, at any time, with respect to any Issuing Bank, the amount set forth opposite the name of such Issuing Bank in the column entitled “Incremental Fronting Limit” on Schedule II (Issuing Bank Limits).

Incremental Issuing Bank” means each Incremental Working Capital Lender identified as an “Incremental Issuing Bank” on Schedule II (Issuing Bank Limits). Each reference to an Incremental Issuing Bank contained in this Agreement and the other Finance Documents shall be deemed to refer to the applicable Incremental Working Capital Lender solely in its capacity as the issuer of Letters of Credit hereunder and not in its capacity as an Incremental Working Capital Lender, and each reference to an Incremental Working Capital Lender contained in this Agreement and the other Finance Documents shall be deemed to refer to such Incremental Working Capital Lender in its capacity as such and not in its capacity (if applicable) as an Incremental Issuing Bank.

Incremental Issuing Bank Limit” means the limitation on the obligation of each Issuing Bank to issue Letters of Credit as identified in the column “Incremental Issuing Bank Limit” on Schedule II (Issuing Bank Limits) with respect to each Issuing Bank.

Incremental Lender” means, as context requires, an Incremental Term Lender or an Incremental Working Capital Lender or both.

Incremental Lender/Issuing Bank” has the meaning given in Section 2.08(b) (Incremental Commitments).

Incremental Non-Fronting Limit” means, at any time, with respect to any Issuing Bank, the amount set forth opposite the name of such Issuing Bank in the column entitled “Incremental Non-Fronting Limit” on Schedule II (Issuing Bank Limits).

Incremental Term Lenders” means those Term Lenders identified on Schedule I (Lenders, Commitments) as having Incremental Term Loan Commitments.

Incremental Term Loan Commitment” means the Incremental Base Term Loan Commitment and the Incremental Contingency Reserve Term Loan Commitment of any Term Lender, and “Incremental Term Loan Commitments” means such commitments of all Incremental Term Lenders in the aggregate.

Incremental Working Capital Commitment” means, with respect to each Working Capital Lender, the commitment of such Working Capital Lender to (i) make Working Capital Loans and (ii) make LC Loans in respect of Fronted Letters of Credit and Non-Fronted Letters of Credit (subject to such Working Capital Lender’s Incremental Non-Fronting Limit as set forth opposite the name of such Working Capital Lender in the column entitled “Incremental Non-Fronting Limit” on Schedule II (Issuing Bank Limits)), in an aggregate amount not to exceed the amount set forth opposite the name of such Working Capital Lender in the column entitled “Incremental Working Capital Commitment” in Schedule I (Lenders, Commitments).

 

11


Incremental Working Capital Lenders” means those Working Capital Lenders identified on Schedule I (Lenders, Commitments) as having Incremental Working Capital Commitments.

Initial Amortization Schedule” means the amortization schedule set forth in Schedule III (Amortization Schedule) calculated based on the Initial Term Loan Amount and the Phase 1 Initial LNG SPA revenues from the no lift case.

Initial Base Term Loan Commitment” means the commitment of a Term Lender to make or otherwise fund a Term Loan pursuant to Section 2.01(a)(i) (Term Loans) prior to the Upsize Closing Date, as set forth opposite the name of such Term Lender in the column entitled “Initial Base Term Loan Commitment” in Schedule I (Lenders, Commitments), and “Initial Base Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

Initial Commitment” means, as context requires, an Initial Term Loan Commitment, an Initial Working Capital Commitment or both.

Initial Contingency Reserve Term Loan Commitment” means the commitment of a Term Lender to make or otherwise fund a Term Loan pursuant to Section 2.01(a)(ii) (Term Loans) prior to the Upsize Closing Date, as set forth opposite the name of such Term Lender in the column entitled “Initial Contingency Reserve Term Loan Commitment” in Schedule I (Lenders, Commitments), and “Initial Contingency Reserve Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

Initial Coordinating Lead Arranger” means each of Bank of America, N.A., Goldman Sachs Bank USA, Mizuho Bank, Ltd., Morgan Stanley Senior Funding, Inc., Banco Santander, S.A., New York Branch, Bank of China, New York Branch, CaixaBank, S.A. an entity registered in the Kingdom of Spain, Deutsche Bank AG, New York Branch, Industrial and Commercial Bank of China Limited, New York Branch, ING Capital LLC, JPMorgan Chase Bank, N.A., Landesbank Baden-Württemberg, New York Branch, MUFG Bank, Ltd., Natixis, New York Branch, Nomura Securities International, Inc., Royal Bank of Canada, Sumitomo Mitsui Banking Corporation and Truist Bank, in each case, not in its individual capacity but as coordinating lead arranger hereunder.

Initial Documentation Bank” means Morgan Stanley Senior Funding, Inc., The Bank of Nova Scotia, Houston Branch and ING Capital LLC, in each case, not in its individual capacity, but as documentation bank.

Initial Fronting Limit” means, at any time, with respect to any Issuing Bank, the amount set forth opposite the name of such Issuing Bank in the column entitled “Initial Fronting Limit” on Schedule II (Issuing Bank Limits).

Initial Issuing Bank” means (a) with respect to the Existing Letters of Credit, each of City National Bank and Bank of America, N.A., as applicable, in its capacity as the issuer thereof, as set forth on Schedule V (Existing Letters of Credit), provided that, (i) City National Bank shall be an Initial Issuing Bank hereunder only with respect to the Existing Letters of Credit issued by it and (ii) for the avoidance of doubt, an issuer of an Existing Letter of Credit shall not be required to be an Initial Working Capital Lender hereunder,

 

12


and (b) with respect to any other Letter of Credit, each Initial Working Capital Lender identified as an “Issuing Bank” on Schedule II (Issuing Bank Limits) with an Initial Fronting Limit or Initial Non-Fronting Limit. Each reference to an Initial Issuing Bank contained in this Agreement and the other Finance Documents shall be deemed to refer to the applicable Initial Working Capital Lender solely in its capacity as the issuer of Letters of Credit hereunder and not in its capacity as an Initial Working Capital Lender, and each reference to an Initial Working Capital Lender contained in this Agreement and the other Finance Documents shall be deemed to refer to such Initial Working Capital Lender in its capacity as such and not in its capacity (if applicable) as an Initial Issuing Bank.

Initial Issuing Bank Limit” means the limitation on the obligation of each Issuing Bank to issue Letters of Credit as identified in the column “Initial Issuing Bank Limit” on Schedule II (Issuing Bank Limits) with respect to each Issuing Bank.

Initial Lender” means, as context requires, an Initial Term Lender or an Initial Working Capital Lender or both.

Initial Non-Fronting Limit” means, at any time, with respect to any Issuing Bank, the amount set forth opposite the name of such Issuing Bank in the column entitled “Initial Non- Fronting Limit” on Schedule II (Issuing Bank Limits).

Initial Term Lenders” means those Term Lenders identified on Schedule I (Lenders, Commitments) as having Initial Term Loan Commitments.

Initial Term Loan Amount” means $8,459,261,411.41, as may be reduced in accordance with Section 4.01(c) (Repayment of Term Loan Advances).

Initial Term Loan Commitment” means the Initial Base Term Loan Commitment and the Initial Contingency Reserve Term Loan Commitment of any Term Lender, and “Initial Term Loan Commitments” means such commitments of all Initial Term Lenders in the aggregate.

Initial Working Capital Commitment” means, with respect to each Working Capital Lender, the commitment of such Working Capital Lender to (i) make Working Capital Loans and (ii) make LC Loans in respect of Fronted Letters of Credit and Non-Fronted Letters of Credit (subject to such Working Capital Lender’s Initial Non-Fronting Limit as set forth opposite the name of such Working Capital Lender in the column entitled “Initial Non-Fronting Limit” on Schedule II (Issuing Bank Limits)), in an aggregate amount not to exceed the amount set forth opposite the name of such Working Capital Lender in the column entitled “Initial Working Capital Commitment” in Schedule I (Lenders, Commitments).

Initial Working Capital Facility” has the meaning provided in the recitals.

Initial Working Capital Lenders” means those Working Capital Lenders identified on Schedule I (Lenders, Commitments) as having Initial Working Capital Commitments.

 

13


Intercompany Loan Agreement” has the meaning provided in the recitals.

Interest Payment Date” has the meaning provided in Section 4.04(a) (Interest Payment Dates).

Interest Period” means in connection with a SOFR Loan, subject, in each case to the availability thereof, an interest period of one (1), three (3) or six (6) months (or, if available to all applicable Lenders, such other periods as may be agreed by the Credit Facility Agent (including with respect to the Applicable Margin agreed to by all the Lenders with respect to any such Interest Period)), as selected by the Borrower in the applicable Disbursement Request or Interest Period Notice, (a) initially, commencing on the Initial Closing Date and ending on June 30, 2022; and (b) thereafter, commencing on the day on which the immediately preceding Interest Period expires; provided that, (i) if an Interest Period would otherwise expire on a day that is not a Business Day, such Interest Period shall expire on the next succeeding Business Day unless no further Business Day occurs in such month, in which case such Interest Period shall expire on the immediately preceding Business Day; (ii) any Interest Period that begins on the last Business Day of a calendar month (or on a day for which there is no numerically corresponding day in the calendar month at the end of such Interest Period) shall, subject to clause (iii) of this definition, end on the last Business Day of a calendar month; (iii) no Interest Period shall extend beyond the Final Maturity Date; and (iv) no tenor that has been removed from this definition pursuant to Section 5.07(d) (Benchmark Replacement Setting) shall be available for specification in such Disbursement Request or Interest Period Notice.

Interest Period Notice” means a notice in substantially the form attached hereto as Exhibit D (Form of Interest Period Notice), executed by an Authorized Officer of the Borrower or, in the case of an Advance, a Disbursement Request.

ISP98” has the meaning given in Section 3.01(g) (Letters of Credit).

Issuing Bank” means (a) the Initial Issuing Banks, (b) the Incremental Issuing Banks and (c) any other Working Capital Lender designated by the Borrower after the Upsize Closing Date that has, or whose credit support provider has, a credit rating of A3 or higher by Moody’s, A- or higher by S&P or an equivalent rating by another nationally-recognized credit rating agency, and that has agreed in writing in its sole discretion to accept such designation as an Issuing Bank and to be bound by all of the terms contained in this Agreement and the other Finance Documents binding on an Issuing Bank in such capacity (provided that, a copy of such agreement has been delivered to the Credit Facility Agent), it being understood that such agreement may contain additional conditions to, or limitations on, such Issuing Bank’s obligation to issue Letters of Credit hereunder (including limits on the aggregate available balance of Letters of Credit at any one time outstanding that may be issued by such Issuing Bank), and any such conditions or limitations are hereby incorporated by reference into this Agreement to the same extent and with the same force as if fully set forth herein. Each reference to an Issuing Bank contained in this Agreement and the other Finance Documents shall be deemed to refer to the applicable Working Capital Lender solely in its capacity as the issuer of Letters of Credit hereunder and not in its capacity as a Working Capital Lender, and each reference to a Working Capital Lender contained in this Agreement and the other Finance Documents shall be deemed to refer to such Working Capital Lender in its capacity as such and not in its capacity (if applicable) as an Issuing Bank.

 

14


Issuing Bank Limit” means, at any time, with respect to any Issuing Bank, the aggregate amount of its Initial Issuing Bank Limit and Incremental Issuing Bank Limit, or, in the case of any Working Capital Lender that becomes an Issuing Bank hereunder pursuant to Section 3.05 (Resignation as an Issuing Bank) or otherwise, such amount as set forth in the agreement evidencing the appointment of such Working Capital Lender as an Issuing Bank, as the same may be (a) reduced from time to time in accordance with Section 2.07 (Termination or Reduction of Commitments), (b) increased from time to time in accordance with Section 2.08 (Incremental Commitments), and (c) reduced or increased from time to time pursuant to assignments by or to such Lender pursuant to Section 11.04 (Assignments).

LC Available Amount” means, for any Letter of Credit on any date of determination, the maximum amount available to be drawn under such Letter of Credit at any time on or after such date (assuming the satisfaction of all conditions for drawing enumerated therein).

LC Cash Collateral Account” means, an interest-bearing cash collateral account established upon the occurrence of a Loan Facility Event of Default by the Credit Facility Agent in its name for the benefit of the Working Capital Lenders and Issuing Banks, subject to the terms of this Agreement and the Common Security and Account Agreement.

LC Exposure” means, as of any time of determination and with respect to any Issuing Bank, the sum of (a) the aggregate undrawn amount of the outstanding Letters of Credit issued by such Issuing Bank at such time plus (b) the aggregate amount of all LC Loans made by such Issuing Bank and in which no other Working Capital Lender is required to participate that have not yet been repaid at such time plus (c) the aggregate amount of LC Reimbursement Payments that the Borrower has not yet repaid and have not yet been converted to LC Loans as of such time.

LC Fee” has the meaning provided in Section 4.15(c) (Fees).

LC Fee Rate” means, during each applicable period set forth in the table shown below, the applicable per annum percentage below:

 

Applicable Period

  

LC Fee Rate

From the Initial Closing Date until the third (3rd) anniversary of the Initial Closing Date

   1.875%

From the third (3rd) anniversary of the Initial Closing Date until the fifth (5th) anniversary of the Initial Closing Date

   2.125%

From the fifth (5th) anniversary of the Initial Closing Date until the Final Maturity Date

   2.375%

LC Loan” means a loan by a Working Capital Lender to the Borrower deemed made pursuant to Section 3.02(c) and Section 3.02(f) (Reimbursement to Issuing Banks).

 

15


LC Payment Notice” has the meaning provided in Section 3.02(a) (Reimbursement to Issuing Banks).

LC Reimbursement Payment” has the meaning provided in Section 3.02(b) (Reimbursement to Issuing Banks).

Lender” means, as context requires, a Term Lender, a Working Capital Lender, or both.

Lender Assignment Agreement” means a Lender Assignment Agreement, substantially in the form of Exhibit E (Form of Lender Assignment Agreement).

Letter of Credit” means (a) each Existing Letter of Credit and (b) each other standby letter of credit substantially in a form attached hereto as (i) Exhibit C-1 (Form of Letter of Credit – TGP), if such letter of credit is to be issued to the counterparty under the agreements described in clause (c) of the definition of “Gas Transportation Agreements” in the Common Terms Agreement, (ii) Exhibit C-2 (Form of Letter of Credit – TETCO), if such letter of credit is to be issued to the counterparty under the agreement described in clause (a) of the definition of “Gas Transportation Agreements” in the Common Terms Agreement, (iii) Exhibit C-3 (Form of Letter of Credit – TETCO), if such letter of credit is to be issued to the counterparty under the agreement described in clause (b) of the definition of “Gas Transportation Agreements” in the Common Terms Agreement, and (iv) such form as is otherwise reasonably acceptable to the Issuing Bank issuing such letter of credit, in each case issued pursuant to Section 3.01 (Letters of Credit) and in accordance with the policies and procedures of such Issuing Bank.

Loan” means, as context requires, a Term Loan, a Working Capital Loan, an LC Loan or each of the foregoing.

Loan Obligations” means, collectively, all Senior Debt Obligations arising under this Agreement, including the Obligors’ obligations to pay, discharge and satisfy the Erroneous Payment Subrogation Rights.

Maximum Rate” has the meaning provided in Section 11.08 (Interest Rate Limitation).

Non-Consenting Lender” means in respect of a Lender, if such Lender has failed to consent to a proposed amendment, waiver, consent or termination which pursuant to the terms of Section 11.01 (Decisions, Amendments, Etc.) requires the consent of all of the Lenders or all affected Lenders and with respect to which Lenders representing at least 50% of the sum of (i) the aggregate undisbursed Commitments plus (ii) the then aggregate outstanding principal amount of the Loans (excluding in each such case any Lender that is a Defaulting Lender or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, a Collateral Party, the Sponsor or any of Sponsor’s Affiliates, and each Commitment and any outstanding principal amount of any Loan of any such Term Lender) or Lenders affected by such proposed amendment, waiver, consent or termination, as the case may be, shall have granted their consent.

Non-Defaulting Lender” means, at any time, a Lender that is not a Defaulting Lender.

 

16


Non-Fronted LC Amount” has the meaning provided in Section 3.01(f) (Letters of Credit).

Non-Fronted Letter of Credit” means a Letter of Credit identified by the Borrower as such in the Request for Issuance.

Non-Fronting Limit” means, at any time, with respect to any Issuing Bank, the aggregate amount of its Initial Non-Fronting Limit and Incremental Non-Fronting Limit, or, in the case of any Working Capital Lender that becomes an Issuing Bank hereunder pursuant to Section 3.05 (Resignation as an Issuing Bank) or otherwise, such amount as set forth in the agreement evidencing the appointment of such Working Capital Lender as an Issuing Bank, as the same may be (a) reduced from time to time in accordance with Section 2.07 (Termination or Reduction of Commitments), (b) increased from time to time in accordance with Section 2.08 (Incremental Commitments), and (c) reduced or increased from time to time pursuant to assignments by or to such Lender pursuant to Section 11.04 (Assignments).

Note” means, as context requires, a Term Loan Note or a Working Capital Loan Note. “Payment Recipient” has the meaning assigned to it in Section 10.15(a) (Erroneous Payments).

Periodic Term SOFR Determination Day” has the meaning provided in the definition of “Term SOFR.”

QFC” has the meaning assigned to the term “qualified financial contract” in, and shall be interpreted in accordance with, 12 U.S.C. 5390(c)(8)(D).

QFC Credit Support” has the meaning provided in Section 11.24 (Acknowledgment Regarding any Supported QFCs).

Register” has the meaning provided in Section 2.06(e) (Funding).

Related Parties” means, with respect to any specified Person, such Person’s Affiliates and the respective shareholders, members, partners, directors, officers, employees, agents, trustees, advisors and representatives of such Person and such Person’s Affiliates.

Relevant Governmental Body” means the Federal Reserve Board or the Federal Reserve Bank of New York, or a committee officially endorsed or convened by the Federal Reserve Board or the Federal Reserve Bank of New York, or any successor thereto.

Request for Issuance” has the meaning provided in Section 3.01(a) (Letters of Credit).

Required Lenders” means at any time, the Lenders holding in excess of 50.00% of the sum of (a) the aggregate undisbursed Commitments plus (b) the then aggregate outstanding principal amount of the Loans (excluding in each such case any Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, an Affiliated Lender, and each Commitment and any outstanding principal amount of any Loan of any such Lender). Such percentage shall be calculated by dividing the number of votes cast in favor of a Decision by the total number of votes cast with respect to such Decision.

 

17


Required Term Lenders” means at any time, the Term Lenders holding in excess of 50.00% of the sum of (a) the aggregate undisbursed Term Loan Commitments plus (b) the then aggregate outstanding principal amount of the Term Loans (excluding in each such case any Term Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, a Collateral Party, the Sponsor or any of Sponsor’s Affiliates, and each Term Loan Commitment and any outstanding principal amount of any Term Loan of any such Term Lender). Such percentage shall be calculated by dividing the number of votes cast in favor of a Decision by the total number of votes cast with respect to such Decision.

Required Working Capital Lenders” means at any time, the Working Capital Lenders holding in excess of 50.00% of the sum of (a) the aggregate undisbursed Working Capital Commitments plus (b) the then-aggregate outstanding principal amount of the Working Capital Loans (excluding in each such case any Working Capital Lender that is a Defaulting Lender or an Affiliate or Subsidiary thereof or, except as otherwise provided in Section 7.4 (Sponsor Voting) of the Common Security and Account Agreement, a Collateral Party, the Sponsor or any of the Sponsor’s Affiliates, and each Working Capital Commitment and any outstanding principal amount of any Working Capital Loan of any such Working Capital Lender). Such percentage shall be calculated by dividing the number of votes cast in favor of a Decision by the total number of votes cast with respect to such Decision.

Resolution Authority” means an EEA Resolution Authority or, with respect to any UK Financial Institution, a UK Resolution Authority.

SOFR” means a rate equal to the secured overnight financing rate as administered by the SOFR Administrator.

SOFR Administrator” means the Federal Reserve Bank of New York (or a successor administrator of the secured overnight financing rate).

SOFR Loan” means a Loan that bears interest at a rate based on Term SOFR, other than pursuant to clause (c) of the definition of “Base Rate.”

Supported QFC” has the meaning provided in Section 11.24 (Acknowledgment Regarding any Supported QFCs).

Term Lenders” means, as context requires, an Initial Term Lender or an Incremental Term Lender or both and each other Person that acquires the rights and obligations of any such Term Lender in accordance with Section 11.04 (Assignments) but excluding any Person that has assigned all of its rights and obligations under the Credit Facility Agreement in accordance with Section 11.04 (Assignments) (other than in connection with the sale of participations) and Participants.

 

18


Term Loan” means, with respect to each Term Lender, each advance to the Borrower of such Term Lender’s pro rata share of the Term Loan Commitment as the Borrower may request under Section 2.02 (Term Loan Availability) and the applicable Disbursement Request.

Term Loan Advance” means each Advance of Term Loans by the Term Lenders (or the Credit Facility Agent on their behalf) on any single date to the Borrower in accordance with Section 2.06 (Funding) and Article VII (Conditions Precedent).

Term Loan Availability Period” has the meaning provided in Section 2.02 (Term Loan Availability).

Term Loan Commitment” means the Base Term Loan Commitment and the Contingency Reserve Term Loan Commitment of any Term Lender, and “Term Loan Commitments” means such commitments of all Term Lenders in the aggregate.

Term Loan Commitment Fee” has the meaning provided in Section 4.15(a) (Fees). “Term Loan Notes” means the promissory notes of the Borrower, substantially in the form of Exhibit B-1 (Form of Term Loan Note) evidencing Term Loans, in each case duly executed and delivered by an Authorized Officer of the Borrower in favor of each Term Lender that requests a Term Loan Note, including any promissory notes issued by the Borrower in connection with assignments of any Term Loan of the Term Lenders.

Term SOFR” means:

(a) for any calculation with respect to a SOFR Loan, the Term SOFR Reference Rate for a tenor comparable to the applicable Interest Period on the day (such day, the “Periodic Term SOFR Determination Day”) that is two (2) U.S. Government Securities Business Days prior to the first day of such Interest Period, as such rate is published by the Term SOFR Administrator; provided that, if as of 5:00 p.m. (New York City time) on any Periodic Term SOFR Determination Day the Term SOFR Reference Rate for the applicable tenor has not been published by the Term SOFR Administrator and a Benchmark Replacement Date with respect to the Term SOFR Reference Rate has not occurred, then Term SOFR will be the Term SOFR Reference Rate for such tenor as published by the Term SOFR Administrator on the first preceding U.S. Government Securities Business Day for which such Term SOFR Reference Rate for such tenor was published by the Term SOFR Administrator so long as such first preceding U.S. Government Securities Business Day is not more than three (3) U.S. Government Securities Business Days prior to such Periodic Term SOFR Determination Day; and

(b) for any calculation with respect to a Base Rate Loan on any day, the Term SOFR Reference Rate for a tenor of one month on the day (such day, the “Base Rate Term SOFR Determination Day”) that is two (2) U.S. Government Securities Business Days prior to such day, as such rate is published by the Term SOFR Administrator; provided that, if as of 5:00 p.m. (New York City time) on any Base Rate Term SOFR Determination Day the Term SOFR Reference Rate for the applicable tenor has not been published by the Term SOFR Administrator and a Benchmark Replacement Date with respect to the Term SOFR Reference Rate has not occurred, then

 

19


Term SOFR will be the Term SOFR Reference Rate for such tenor as published by the Term SOFR Administrator on the first preceding U.S. Government Securities Business Day for which such Term SOFR Reference Rate for such tenor was published by the Term SOFR Administrator so long as such first preceding U.S. Government Securities Business Day is not more than three (3) U.S. Government Securities Business Days prior to such Base Rate Term SOFR Determination Day;

provided further that, if Term SOFR determined as provided above (including pursuant to the proviso under clause (a) or clause (b) above) shall ever be less than the Floor, then Term SOFR shall be deemed to be the Floor.

Term SOFR Administrator” means CME Group Benchmark Administration Limited (CBA) (or a successor administrator of the Term SOFR Reference Rate selected by the Credit Facility Agent in its reasonable discretion).

Term SOFR Reference Rate” means the forward-looking term rate based on SOFR. “Trade Date” has the meaning provided in Section 11.04(b) (Assignments).

Type” means, when used in reference to:

(a) any Loan or Advance, or the Loans constituting such Advance, Term Loans and/or Working Capital Loans (or any Type thereof) as the context requires; and

(b) any Commitment, a Term Loan Commitment and/or a Working Capital Commitment as the context requires.

UCP 600” has the meaning provided in Section 3.01(g)(iii) (Letters of Credit).

UK Financial Institution” means any BRRD Undertaking (as such term is defined under the PRA Rulebook (as amended from time to time) promulgated by the United Kingdom Prudential Regulation Authority) or any person falling within IFPRU 11.6 of the FCA Handbook (as amended from time to time) promulgated by the United Kingdom Financial Conduct Authority, which includes certain credit institutions and investment firms, and certain affiliates of such credit institutions or investment firms.

UK Resolution Authority” means the Bank of England or any other public administrative authority having responsibility for the resolution of any UK Financial Institution.

Unadjusted Benchmark Replacement” means the applicable Benchmark Replacement excluding the related Benchmark Replacement Adjustment.

Undisclosed Administration” means, in relation to a Lender or its direct or indirect parent company, the appointment of an administrator, provisional liquidator, conservator, receiver, trustee, custodian, or other similar official by a supervisory authority or regulator under or based on the law in the country where such Lender or such parent company is subject to home jurisdiction supervision, if applicable law requires that such appointment not be publicly disclosed.

 

20


Upsize Amortization Schedule” has the meaning given in Section 4.01(b) (Repayment of Term Loan Advances).

Upsize Coordinating Lead Arranger” means each of Banco Santander, S.A., Bank of America, N.A., Bank of China, New York Branch, The Bank of Nova Scotia, Houston Branch, CaixaBank S.A., Deutsche Bank AG, New York Branch, Goldman Sachs Bank USA, ING Capital LLC, JPMorgan Chase Bank, N.A., Landesbank Baden-Württemberg, New York Branch, Mizuho Bank, Ltd., MUFG Bank, Ltd., Natixis, New York Branch, Royal Bank of Canada, Sumitomo Mitsui Banking Corporation, Banco Bilbao Vizcaya Argentaria, S.A. New York Branch, and Wells Fargo Bank, N.A. in each case, not in its individual capacity but as coordinating lead arranger hereunder.

Upsize Documentation Bank” means The Bank of Nova Scotia, Houston Branch and ING Capital LLC in each case, not in its individual capacity, but as documentation bank.

U.S. Government Securities Business Day” means any day except for (a) a Saturday, (b) a Sunday or (c) a day on which the Securities Industry and Financial Markets Association recommends that the fixed income departments of its members be closed for the entire day for purposes of trading in United States government securities.

U.S. Special Resolution Regimes” has the meaning provided in Section 11.24 (Acknowledgment Regarding any Supported QFCs).

Working Capital Advance” means each Advance of Working Capital Loans by or on behalf of the Working Capital Lenders on any single date to the Borrower in accordance with Section 2.06 (Funding) and Article VII (Conditions Precedent).

Working Capital Commitment” means, as context requires, an Initial Working Capital Commitment or an Incremental Working Capital Commitment or both or if any Working Capital Lender has entered into one or more Lender Assignment Agreements, such amount as set forth opposite the name of such Working Capital Lender in the Register maintained by the Credit Facility Agent as such Working Capital Lender’s commitment, as the same may be (a) reduced from time to time in accordance with Section 2.07 (Termination or Reduction of Commitments), (b) increased from time to time in accordance with Section 2.08 (Incremental Commitments), (c) reduced or increased from time to time pursuant to assignments by or to such Working Capital Lender pursuant to Section 11.04 (Assignments) and (d) utilized, as of the applicable date of determination, in the amount of such Working Capital Lender’s Working Capital Commitment Exposure.

Working Capital Commitment Exposure” means as of any time of determination and with respect to each Working Capital Lender, the sum of (i) the principal amount of its Working Capital Loans outstanding, plus (ii) the principal amount of its LC Loans outstanding, plus (iii) in the case of each Working Capital Lender that is an Issuing Bank, the aggregate undrawn amount of the outstanding Letters of Credit issued by it (excluding the aggregate amount thereof in respect of which other Working Capital Lenders are required to participate), plus (iv) aggregate LC Reimbursement Payments that have not yet converted to LC Loans under the outstanding Letters of Credit issued by it (excluding the aggregate amount thereof in respect of which other Working Capital Lenders are required to participate) plus (v) the aggregate amount of such Working Capital Lender’s participations in Letters of Credit issued by other Issuing Banks.

 

21


Working Capital Commitment Fee” has the meaning provided in Section 4.15(b) (Fees).

Working Capital Commitment Increase” has the meaning provided in Section 2.08(a) (Incremental Commitments).

Working Capital Commitment Increase Notice” has the meaning provided in Section 2.08(a) (Incremental Commitments).

Working Capital Facility” has the meaning provided in the recitals.

Working Capital Lender Payment Notice” has the meaning provided in Section 3.02(c) (Reimbursement to Issuing Banks).

Working Capital Lenders” means, as context requires, an Initial Working Capital Lender or an Incremental Working Capital Lender or both and each other Person that acquires the rights and obligations of any such Working Capital Lender in accordance with Section 11.04 (Assignments) but excluding any Person that has assigned all of its rights and obligations under the Credit Facility Agreement in accordance with Section 11.04 (Assignments) (other than in connection with the sale of participations) and Participants.

Working Capital Loan” has the meaning provided in Section 2.04(a) (Working Capital Loan Availability).

Working Capital Loan Availability Period” has the meaning provided in Section 2.04(a) (Working Capital Loan Availability).

Working Capital Loan Note” means the promissory notes of the Borrower, substantially in the form of Exhibit B-2 (Form of Working Capital Note) evidencing Working Capital Loans, in each case duly executed and delivered by an Authorized Officer of the Borrower in favor of each Working Capital Lender that requests a Working Capital Loan Note, including any promissory notes issued by the Borrower in connection with assignments of any Working Capital Loan of the Working Capital Lenders.

Working Capital Loan Termination Date” has the meaning provided in Section 2.04(a) (Working Capital Loan Availability).

Write-Down and Conversion Powers” means, (a) with respect to any EEA Resolution Authority, the write-down and conversion powers of such EEA Resolution Authority from time to time under the Bail-In Legislation for the applicable EEA Member Country, which write-down and conversion powers are described in the EU Bail-In Legislation Schedule, and (b) with respect to the United Kingdom, any powers of the applicable Resolution Authority under the Bail-In Legislation to cancel, reduce, modify or change the

 

22


form of a liability of any UK Financial Institution or any contract or instrument under which that liability arises, to convert all or part of that liability into shares, securities or obligations of that person or any other person, to provide that any such contract or instrument is to have effect as if a right had been exercised under it or to suspend any obligation in respect of that liability or any of the powers under that Bail-In Legislation that are related to or ancillary to any of those powers.

 

23


EXHIBIT B-1 TO

CREDIT FACILITY AGREEMENT

Form Of Term Loan Note

[Omitted]


EXHIBIT B-2 TO

CREDIT FACILITY AGREEMENT

Form Of Working Capital Loan Note

[Omitted]


EXHIBIT C-1 TO

CREDIT FACILITY AGREEMENT

Form Of Letter of Credit – TGP

[Omitted]


EXHIBIT C-2 TO

CREDIT FACILITY AGREEMENT

Form Of Letter of Credit – TETCO

[Omitted]


EXHIBIT C-3 TO

CREDIT FACILITY AGREEMENT

Form Of Letter of Credit – TETCO

[Omitted]


EXHIBIT D TO

CREDIT FACILITY AGREEMENT

Form Of Interest Period Notice

[Omitted]


EXHIBIT E TO

CREDIT FACILITY AGREEMENT

Form Of Lender Assignment Agreement

[Omitted]

Exhibit 10.87

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

AMENDED AND RESTATED COMMON TERMS AGREEMENT

FOR THE LOANS

among

 

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC,

as Borrower,

 

 

VENTURE GLOBAL GATOR EXPRESS, LLC,

as Guarantor,

 

 

NATIXIS, NEW YORK BRANCH,

as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties,

Each other Facility Agent that is Party hereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement

and

ROYAL BANK OF CANADA,

as Intercreditor Agent for the Facility Lenders

 

 

Dated as of March 13, 2023


CONTENTS

 

             Page  
1.   DEFINITIONS AND INTERPRETATION      1  
2.   GENERAL PRINCIPLES OF THE LOANS      1  
  2.1  

Purpose and Scope of the Loans

     1  
  2.2  

Sequence of Advances of Senior Debt

     2  
  2.3  

Loan Disbursement and Letter of Credit Issuance Procedures

     2  
  2.4  

Pro Rata Advances

     4  
     2.5  

Interest

     4  
  2.6  

Currency

     4  
  2.7  

Acknowledgement and Consent to Bail-In of Affected Financial Institutions

     5  
  2.8  

Acknowledgement Regarding Any Supported QFCs

     6  
3.   REPAYMENT, PREPAYMENT AND CANCELLATION      7  
  3.1  

CTA Payment Dates

     7  
  3.2  

Right of Repayment and Cancellation in Relation to a Single Facility Lender

     8  
  3.3  

No Repayments or Prepayments

     9  
  3.4  

Mandatory Prepayments

     9  
  3.5  

Voluntary Prepayments

     14  
  3.6  

Prepayment Fees and Funding Losses

     15  
  3.7  

Pro Rata Payment

     15  
  3.8  

Reductions and Cancellations of Facility Debt Commitments

     17  
  3.9  

Late Payments

     18  
  3.10  

No Borrowing or Reinstatement

     19  
4.   CONDITIONS PRECEDENT      19  
  4.1  

Conditions to Initial Closing Date and Initial Advance

     19  
  4.2  

Conditions to Upsize Closing Date

     30  
  4.3  

Conditions to Each Term Loan Advance

     40  
  4.4  

Conditions to Each Advance under the Working Capital Facility

     44  
  4.5  

Satisfaction of Conditions

     45  
5.   REPRESENTATIONS AND WARRANTIES OF THE OBLIGORS      46  
  5.1  

Initial Representations and Warranties of the Obligors

     46  
  5.2  

Repeated Representations and Warranties of the Obligors

     56  

 

-i-

Plaquemines – Amended & Restated Common Terms Agreement


6.   INCURRENCE OF ADDITIONAL SENIOR DEBT      63  
     6.1  

Permitted Senior Debt

     63  
  6.2  

Working Capital Debt

     64  
  6.3  

Replacement Debt

     66  
7.   PERMITTED DEVELOPMENT EXPENDITURES/EXPANSIONS      69  
  7.1  

Permitted Development Expenditures

     69  
  7.2  

Expansion Contracts

     69  
8.   LNG SPA COVENANTS      70  
  8.1  

LNG SPA Maintenance

     70  
  8.2  

LNG SPA Mandatory Prepayment

     73  
  8.3  

Amendment of LNG SPAs

     76  
  8.4  

Sale of Supplemental Quantity

     77  
  8.5  

Sale of Pre-Completion Quantities

     78  
  8.6  

Payment of LNG Sales Proceeds

     79  
  8.7  

DPU Shipping Agreement

     79  
9.   MATERIAL CONSTRUCTION CONTRACTS      79  
  9.1  

Change Orders

     79  
  9.2  

UOP Pre-Treatment Systems

     81  
10.   REPORTING BY THE BORROWER      81  
  10.1  

Accounting, Financial and Other Information

     81  
  10.2  

Quarterly Historical DSCR Certificate

     83  
  10.3  

Notices

     83  
  10.4  

Construction Reports

     85  
  10.5  

Operating Budget

     89  
  10.6  

Operating Statements and Reports

     90  
  10.7  

Insurance Reporting

     92  
  10.8  

Copies of Finance Documents

     93  
  10.9  

Construction Budget and Schedule

     94  
11.   RESTRICTED PAYMENTS      94  
  11.1  

Conditions to Restricted Payments

     94  
  11.2  

Certain Restricted Payments

     95  
  11.3  

Project Phase 1 Pre-Completion Revenue Restricted Payments

     96  
  11.4  

Project Phase 2 Pre-Completion Revenue Restricted Payments

     97  

 

-ii-

Plaquemines – Amended & Restated Common Terms Agreement


12.   OBLIGOR COVENANTS      99  
  12.1  

Use of Proceeds

     99  
  12.2  

Maintenance of Existence, Franchises, Etc.

     99  
  12.3  

Project Construction; Maintenance of Properties

     100  
  12.4  

Books and Records; Inspection Rights

     101  
  12.5  

Material Project Agreements

     102  
  12.6  

Compliance with Law

     107  
  12.7  

Environmental Compliance

     108  
     12.8  

Permits

     109  
  12.9  

Export Authorizations

     109  
  12.10  

FERC Order

     109  
  12.11  

Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages

     110  
  12.12  

Inspection Rights

     110  
  12.13  

Taxes

     110  
  12.14  

Limitation on Indebtedness

     110  
  12.15  

Guarantees

     112  
  12.16  

Limitation on Liens

     112  
  12.17  

Sale of Project Property

     113  
  12.18  

Merger, Division, Liquidation and Sale of All Assets

     114  
  12.19  

Limitation on Investments and Loans

     114  
  12.20  

Nature of Business

     114  
  12.21  

Transactions with Affiliates

     115  
  12.22  

Hedging Arrangements

     116  
  12.23  

Accounts

     117  
  12.24  

Separateness

     117  
  12.25  

Historical DSCR

     119  
  12.26  

Auditors

     119  
  12.27  

Gas Transportation Arrangements; Gas Purchase Arrangements

     119  
  12.28  

Insurance Covenant

     120  
  12.29  

Certain Real Property Rights; Real Property Documents; Leases

     121  
  12.30  

Margin Regulation

     121  
  12.31  

Further Assurances

     122  
  12.32  

As-Built Survey

     122  
  12.33  

ERISA

     122  
13.   CONSULTANTS      123  
  13.1  

Appointment of Consultants

     123  
  13.2  

Replacement and Fees

     123  
  13.3  

Access

     124  

 

-iii-

Plaquemines – Amended & Restated Common Terms Agreement


14.   CONDITIONS TO COMPLETION; PROJECT COMPLETION DATEs WATERFALLs      125  
  14.1  

Conditions to Occurrence of the Project Phase 1 Completion Date

     125  
  14.2  

Project Phase 1 Completion Date Transfers

     130  
  14.3  

Conditions to Occurrence of the Project Phase 2 Completion Date

     130  
  14.4  

Project Phase 2 Completion Date Waterfall

     135  
15.   LOAN FACILITY EVENTS OF DEFAULT      136  
  15.1  

Loan Facility Events of Default

     136  
  15.2  

Declaration of Loan Facility Declared Default

     143  
  15.3  

Cessation of Loan Facility Declared Default

     143  
     15.4  

Instruction to Intercreditor Agent

     143  
16.   COMMON REMEDIES AND ENFORCEMENT      144  
  16.1  

Facility Lender Remedies for Loan Facility Declared Events of Default

     144  
  16.2  

Remedies for Events of Default under Facility Agreements

     145  
 

16.3

 

Permitted Actions under Common Security and Account Agreement

     145  
17.   INTERCREDITOR ARRANGEMENTS      145  
  17.1  

Facility Agents; Facility Lender Action

     145  
  17.2  

Agreement to Comply with Intercreditor Agreement

     146  
  17.3  

Agreement Not to Amend Entrenched Intercreditor Provisions

     146  
18.   THE INTERCREDITOR AGENT      147  
  18.1  

Intercreditor Agreement

     147  
  18.2  

Relationship

     148  
  18.3  

Delivery of Documentation

     148  
  18.4  

Liability

     148  
  18.5  

Exoneration

     148  
  18.6  

Reliance

     149  
  18.7  

Resignation and Succession

     149  
19.   CHANGES TO THE PARTIES      150  
  19.1  

Represented Parties; Successors and Assigns

     150  
  19.2  

Transfers by the Obligors

     150  
  19.3  

Replacement of Facility Agents

     150  
  19.4   Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement      151  
  19.5  

Mitigation Obligations; Replacement of Lenders

     153  
  19.6  

Transfers by a Facility Lender

     156  
  19.7  

Register

     156  
  19.8  

Resulting Increased Costs

     156  

 

-iv-

Plaquemines – Amended & Restated Common Terms Agreement


20.   SUBORDINATION      157  
  20.1  

Subordination

     157  
21.   TAX GROSS-UP AND INDEMNITIES      157  
     21.1  

Withholding Tax Gross-Up

     157  
  21.2  

Payment of Other Taxes

     158  
  21.3  

Indemnification by the Borrower

     158  
  21.4  

Indemnification by the Facility Lenders

     158  
  21.5  

Status of Facility Lenders and Facility Agents

     159  
  21.6  

Refunds

     162  
  21.7  

Evidence of Payments

     162  
  21.8  

Survival

     163  
  21.9  

Defined Terms

     163  
22.   INCREASED COSTS      163  
  22.1  

Increased Costs

     163  
  22.2  

Relationship Between Increased Costs and Taxes

     165  
23.   MISCELLANEOUS      166  
  23.1  

Termination

     166  
  23.2  

Right of Set-Off

     166  
  23.3  

Waiver of Immunity

     167  
  23.4  

Expenses

     167  
  23.5  

Calculation of Floating Rate Obligations

     169  
  23.6  

Severability

     169  
  23.7  

Confidentiality

     170  
  23.8  

Notices

     170  
  23.9  

Successors and Assigns; Benefits of Agreement

     173  
  23.10  

Remedies

     173  
  23.11  

Execution in Counterparts; E-Signature

     174  
  23.12  

Governing Law

     175  
  23.13  

Waiver of Jury Trial

     175  
  23.14  

Consent to Jurisdiction

     175  
  23.15  

Amendments

     176  
  23.16  

Conflicts

     177  
  23.17  

Effectiveness

     177  
  23.18  

Limitations on Liability

     177  
  23.19  

Survival of Obligations

     177  

 

-v-

Plaquemines – Amended & Restated Common Terms Agreement


  23.20  

No Fiduciary Duty

     178  
  23.21  

USA Patriot Act Notice

     178  
  23.22  

Limited Recourse

     179  
     23.23  

Entire Agreement

     180  
  23.24  

Tax Treatment

     181  
  23.25  

Amendment and Restatement

     181  

 

-vi-

Plaquemines – Amended & Restated Common Terms Agreement


SCHEDULES

 

Schedule 5.1(f)(ii) Prior Locations

     5.1 (f)(ii)-1 

Schedule 5.2(m) Real Property Interests

     5.2 (m)-1 

Schedule A Common Definitions and Rules of Interpretation

     A-1  

Schedule B – 1 Disbursement Request Form (Term Loans)

     B-1  

Schedule B – 2 Disbursement Request Form (Working Capital Loans)

     B-2  

Schedule B – 3 Issuance Request Form (Letters of Credit)

     B-3  

Schedule C – 1 Table of Requirements for Legal Opinions – Conditions to Initial ClosingC-1

  

Schedule C – 2 Table of Requirements for Legal Opinions – Conditions to Upsize Closing

     C-2  

Schedule D – 1 Construction Budget and Schedule – Construction Budget

     D-1  

Schedule D – 2 Construction Budget and Schedule – Construction Schedule

     D-2  

Schedule E Know Your Customer Documentation

     E-1  

Schedule F Material Permits

     F-1  

Schedule G Disclosure Schedule

     G-1  

Schedule H Material Project Agreements and Certain Other Contracts

     H-1  

Schedule I Change Orders

     I-1  

[Reserved]

     J-1  

Schedule K Gas Sourcing Plan

     K-1  

Schedule L Schedule of Minimum Insurance

     L-1  

Schedule M Independent Insurance Experts

     M-1  

Schedule N Senior Creditors’ Advisors and Consultants

     N-1  

Schedule O – 1 Phase 1 Lenders’ Reliability Test Criteria

     O-1  

Schedule O – 2 Lenders’ Reliability Test Criteria

     O-2  

Schedule P – 1 Replacement Facility Agent Accession Agreement

     P-1  

Schedule P – 2 New Facility Agent Accession Agreement (Additional Senior Debt)

     P-2  

Schedule Q – 1 Addresses For Notices To Obligors

     Q-1  

Schedule Q – 2 Addresses For Notices To Facility Agents And Facility Lenders

     Q-2  

Schedule R Base Case Forecast

     R-1  

Schedule S – 1 Form of General Subordination Agreement

     S-1  

Schedule S – 2 Form of Obligor Subordination Agreement

     S-2  

 

-vii-

Plaquemines – Amended & Restated Common Terms Agreement


Schedule T Knowledge Parties

     T-1  

Schedule U Real Property Documents

     U-1  

Schedule V Schedule of Certain Real Property Rights

     V-1  

Schedule W Form of Disbursement Endorsement

     W-1  

Schedule X Phase I Environmental Assessments

     X-1  

Schedule Y Disqualified Institutions

     Y-1  

Schedule Z Disqualified Advisors

     Z-1  

Schedule AA Survey Endorsements

     AA-1  

Schedule BB Shipping Agency Term Sheet

     BB-1  

 

-viii-

Plaquemines – Amended & Restated Common Terms Agreement


AMENDED AND RESTATED COMMON TERMS AGREEMENT

FOR THE LOANS

This AMENDED AND RESTATED COMMON TERMS AGREEMENT FOR THE LOANS, dated as of March 13, 2023 (the “Common Terms Agreement” or this “Agreement”), is made among:

 

  i.

VENTURE GLOBAL PLAQUEMINES LNG, LLC, a limited liability company organized under the laws of the State of Delaware (the “Borrower”),

 

  ii.

VENTURE GLOBAL GATOR EXPRESS, LLC, a limited liability company organized under the laws of the State of Delaware (the “Guarantor”),

 

  iii.

NATIXIS, NEW YORK BRANCH, as the Facility Agent for the Credit Facility Lender Parties under the Credit Facility Agreement on behalf of itself and the Credit Facility Lender Parties (the “Credit Facility Agent”),

 

  iv.

each other Facility Agent that is Party hereto from time to time in accordance with this Agreement and the other Finance Documents on behalf of itself and the Facility Lenders under its Facility Agreement, and

 

  v.

ROYAL BANK OF CANADA, as the intercreditor agent for the Facility Lenders on the terms and conditions set forth in the Intercreditor Agreement (in such capacity, the “Intercreditor Agent”).

 

1.

DEFINITIONS AND INTERPRETATION

 

  (a)

Except as otherwise expressly provided herein, capitalized terms used in this Agreement and its Schedules shall have the meanings assigned to them in Section 1.3 of Schedule A (Common Definitions and Rules of Interpretation Definitions).

 

  (b)

In this Agreement and the Schedules hereto, except as otherwise expressly provided herein, the interpretation provisions contained in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation – Interpretation) shall apply.

 

2.

GENERAL PRINCIPLES OF THE LOANS

 

  2.1

Purpose and Scope of the Loans

 

  (a)

The Borrower shall use the proceeds of the Upsized Senior Debt solely in accordance with Section 12.1 (Use of Proceeds).

 

-1-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

The Borrower shall use the proceeds of any Senior Debt other than the Upsized Senior Debt for the respective purposes specified in the relevant Facility Agreement or other applicable Senior Debt Instrument or Permitted Senior Debt Hedging Instrument pursuant to which such Senior Debt is incurred.

 

  (c)

No Facility Lender or Facility Agent or the Intercreditor Agent is bound to monitor or verify the application of any amount borrowed by the Borrower pursuant to this Agreement or any other Finance Document.

 

  2.2

Sequence of Advances of Senior Debt

 

  (a)

Subject to the satisfaction (or waiver) of the applicable conditions in Article 4 (Conditions Precedent) and during the Term Loan Availability Period and/or Working Capital Loan Availability Period, as applicable, Advances by the Credit Facility Lenders under the Credit Facility Agreement in respect of Term Loan Commitments shall be utilized in a 75:25 ratio with Equity Funding (or if any Equity Funding has been funded in excess of a pro rata contribution, the Term Loans shall be funded without additional Equity Funding until a 75:25 Senior Debt/Equity Ratio is achieved).

 

  (b)

The sequencing of Advances under any Senior Debt (including Additional Senior Debt) other than the Upsized Senior Debt shall be as set forth in the Senior Debt Instrument for such Senior Debt.

 

  2.3

Loan Disbursement and Letter of Credit Issuance Procedures

 

  (a)

All disbursements of Loans shall be made to the Borrower.

 

  (b)

Disbursements of Loans and, as applicable, issuances of letters of credit shall be requested by the Borrower in a duly completed Disbursement Request substantially in the form set forth in Schedule B-1 (Disbursement Request Form (Term Loans)), Schedule B-2 (Disbursement Request Form (Working Capital Loans)) or Schedule B-3 (Issuance Request Form (Letters of Credit)) (or in such other form as may be required pursuant to a Facility Agreement) and, with respect to Loans, may be requested no more frequently than twice in any calendar month, except:

 

  (i)

as required for payment of interest and commitment fees during the Availability Period; or

 

  (ii)

as otherwise provided in the relevant Facility Agreement.

 

  (c)

The Borrower shall request disbursements of Loans by delivering to the Intercreditor Agent and each Facility Agent in respect of the Loans being requested a Disbursement Request in accordance with Section 2.4 (Pro Rata Advances) and the terms of the relevant Facility Agreement.

 

-2-

Plaquemines – Amended & Restated Common Terms Agreement


  (d)

Each Disbursement Request shall be irrevocable and the obligation of each Facility Lender to make an Advance under its Facility Agreement shall be subject to:

 

  (i)

with respect to the Initial Advance of the Term Loans, the prior satisfaction or waiver of each of the common conditions precedent set forth in Section 4.1 (Conditions to Initial Closing Date and Initial Advance) and Section 4.3 (Conditions to Each Term Loan Advance);

 

  (ii)

with respect to the issuance of any letters of credit under the Working Capital Facility required to be issued as of the Initial Closing Date, the prior satisfaction or waiver of each of the common conditions precedent set forth in Section 4.1 (Conditions to Initial Closing Date and Initial Advance) and Section 4.4 (Conditions to Each Advance under the Working Capital Facility);

 

  (iii)

with respect to the issuance of any letters of credit under the Working Capital Facility required to be issued on the Upsize Closing Date, the prior satisfaction or waiver of each of the common conditions precedent set forth in Section 4.2 (Conditions to Upsize Closing Date) and Section 4.4 (Conditions to Each Advance under the Working Capital Facility);

 

  (iv)

with respect to any Advance of the Term Loans (other than the Initial Advance made as of the Initial Closing Date), the prior satisfaction or waiver of each of the common conditions precedent set forth in Section 4.3 (Conditions to Each Term Loan Advance); provided that, for any Advance of the Term Loans made after the Upsize Closing Date, each of the common conditions precedent set forth in Section 4.2 (Conditions to Upsize Closing Date) have previously been satisfied or waived;

 

  (v)

with respect to any Advance under the Working Capital Facility, including issuance of letters of credit thereunder (other than the issuance of any letters of credit under the Working Capital Facility required to be issued as of the Initial Closing Date or on the Upsize Closing Date), the prior satisfaction or waiver of each of the common conditions precedent set forth in Section 4.4 (Conditions to Each Advance under the Working Capital Facility); and

 

  (vi)

with respect to any Advance made under any other Facility Agreement, the prior satisfaction of each of the conditions precedent to such Advance set forth in such Facility Agreement.

 

-3-

Plaquemines – Amended & Restated Common Terms Agreement


  2.4

Pro Rata Advances

 

  (a)

Except with respect to (i) any Facility Debt Commitments that have been suspended pursuant to any Facility Agreement, (ii) Loans the proceeds of which are to be used for specified purposes, including Working Capital Debt, as specified in the applicable Facility Agreements, and (iii) Advances to pay interest and commitment fees during the Availability Period under a respective Facility Agreement (which shall be borrowed pursuant to the terms of such respective Facility Agreement), the Borrower shall borrow concurrently under each of the Facility Agreements whose Facility Debt Commitments have not been fully borrowed or cancelled and shall borrow pro rata in the proportion that the unborrowed portion of each Facility Lender’s Facility Debt Commitment bears to the total of the unborrowed portion of the Senior Debt Commitments of all relevant Facility Lenders under the applicable Facility Agreements. If Advances cannot be made exactly pro rata due solely to minimum disbursement amounts and required integral multiples of disbursements under any Facility Agreement, Advances shall be made in amounts as near to such exactly proportionate amounts as possible, to the extent reasonably practicable and in a manner that is consistent, fair and equitable across affected Facility Agreements, and shall be deemed to be Advances in compliance with this Section 2.4 (Pro Rata Advances).

 

  (b)

The Borrower shall promptly notify the Intercreditor Agent (providing reasonably sufficient details) if funds are not received from any Facility Lender by the close of business on the next succeeding Business Day after the date on which any such disbursement is due to be received.

 

  2.5

Interest

Interest shall accrue on each Loan at the times and in the amounts specified in the relevant Facility Agreement.

 

  2.6

Currency

 

  (a)

The Borrower shall only submit a Disbursement Request denominated in whole US Dollars except in the case of:

 

  (i)

the final Advance under a Facility Agreement; and

 

  (ii)

any Advance, in whole or in part, in respect of the payment of interest or commitment fees.

 

  (b)

All Loans shall be stated, made and disbursed in US Dollars.

 

-4-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

The portion of any Advance comprising funds under any Facility Agreement shall not exceed the available Facility Debt Commitment under such Facility Agreement.

 

  (d)

The minimum quantum of any Advance under a Facility Agreement shall be as specified in such Facility Agreement.

 

  (e)

The Borrower shall make all payments of any amount with respect to the Loans (whether comprising fees, interest, principal, premium, if any, or Funding Losses) in US Dollars.

 

  2.7

Acknowledgement and Consent to Bail-In of Affected Financial Institutions

Notwithstanding anything to the contrary in any Finance Document or in any other agreement, arrangement or understanding among any such parties, each party hereto acknowledges that any liability of any Affected Financial Institution arising under any Finance Document, to the extent such liability is unsecured, may be subject to the Write-Down and Conversion Powers of the applicable Resolution Authority and agrees and consents to, and acknowledges and agrees to be bound by:

 

  (a)

the application of any Write-Down and Conversion Powers by the applicable Resolution Authority to any such liabilities arising hereunder which may be payable to it by any party hereto that is an Affected Financial Institution; and

 

  (b)

the effects of any Bail-in Action on any such liability, including, if applicable:

 

  (i)

a reduction in full or in part or cancellation of any such liability;

 

  (ii)

a conversion of all, or a portion of, such liability into shares or other instruments of ownership in such Affected Financial Institution, its parent undertaking, or a bridge institution that may be issued to it or otherwise conferred on it, and that such shares or other instruments of ownership will be accepted by it in lieu of any rights with respect to any such liability under this Agreement or any other Finance Document; or

 

  (iii)

the variation of the terms of such liability in connection with the exercise of the Write-Down and Conversion Powers of the applicable Resolution Authority.

 

-5-

Plaquemines – Amended & Restated Common Terms Agreement


  2.8

Acknowledgement Regarding Any Supported QFCs

To the extent that the Finance Documents provide support, through a guarantee or otherwise, for Permitted Hedging Instruments or any other agreement or instrument that is a QFC (such support, “QFC Credit Support” and each such QFC a “Supported QFC”), the parties acknowledge and agree as follows with respect to the resolution power of the Federal Deposit Insurance Corporation under the Federal Deposit Insurance Act and Title II of the Dodd-Frank Wall Street Reform and Consumer Protection Act (together with the regulations promulgated thereunder, the “U.S. Special Resolution Regimes”) in respect of such Supported QFC and QFC Credit Support (with the provisions below applicable notwithstanding that the Finance Documents and any Supported QFC may in fact be stated to be governed by the laws of the State of New York and/or of the United States or any other state of the United States):

 

  (a)

In the event a Covered Entity that is party to a Supported QFC (each, a “Covered Party”) becomes subject to a proceeding under a U.S. Special Resolution Regime, the transfer of such Supported QFC and the benefit of such QFC Credit Support (and any interest and obligation in or under such Supported QFC and such QFC Credit Support, and any rights in property securing such Supported QFC or such QFC Credit Support) from such Covered Party will be effective to the same extent as the transfer would be effective under the U.S. Special Resolution Regime if the Supported QFC and such QFC Credit Support (and any such interest, obligation and rights in property) were governed by the laws of the United States or a state of the United States. In the event a Covered Party or a BHC Act Affiliate of a Covered Party becomes subject to a proceeding under a U.S. Special Resolution Regime, Default Rights under the Finance Documents that might otherwise apply to such Supported QFC or any QFC Credit Support that may be exercised against such Covered Party are permitted to be exercised to no greater extent than such Default Rights could be exercised under the U.S. Special Resolution Regime if the Supported QFC and the Finance Documents were governed by the laws of the United States or a state of the United States. Without limitation of the foregoing, it is understood and agreed that rights and remedies of the parties with respect to a Defaulting Lender shall in no event affect the rights of any Covered Party with respect to a Supported QFC or any QFC Credit Support.

 

  (b)

As used in this Section 2.8 (Acknowledgement Regarding Any Supported QFCs), the following terms have the following meanings:

 

  (i)

BHC Act Affiliate” of a party means an “affiliate” (as such term is defined under, and interpreted in accordance with, 12 U.S.C. 1841(k)) of such party.

 

-6-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

Covered Entity” means any of the following:

 

  (A)

a “covered entity” as that term is defined in, and interpreted in accordance with, 12 C.F.R. §252.82(b);

 

  (B)

a “covered bank” as that term is defined in, and interpreted in accordance with, 12 C.F.R. §47.3(b); or

 

  (C)

a “covered FSI” as that term is defined in, and interpreted in accordance with, 12 C.F.R. §382.2(b).

 

  (iii)

Default Right” has the meaning assigned to that term in, and shall be interpreted in accordance with, 12 C.F.R. §§ 252.81, 47.2 or 382.1, as applicable.

 

  (iv)

QFC” has the meaning assigned to the term “qualified financial contract” in, and shall be interpreted in accordance with, 12 U.S.C. 5390(c)(8)(D).

 

3.

REPAYMENT, PREPAYMENT AND CANCELLATION

 

  3.1

CTA Payment Dates

 

  (a)

Subject to the relevant Facility Agreement, the Borrower shall pay the interest, and repay the principal on each Loan made available to it under each Facility Agreement in installments, which shall be payable on each CTA Payment Date up to and including the Final Maturity Date under such Facility Agreement.

 

  (b)

The Borrower shall ensure that any Senior Debt Instrument (other than any Indenture) provides that the dates for payment of principal under each such Senior Debt Instrument coincide with the Quarterly Payment Dates.

 

  (c)

The interest periods, date of first payment of interest and date of first repayment of principal in respect of Loans shall be as specified in the Facility Agreements.

 

  (d)

The amount of Senior Debt Obligations payable by the Borrower on any CTA Payment Date shall be calculated in accordance with the provisions of the Senior Debt Instrument or Permitted Senior Debt Hedging Instrument pursuant to which such Senior Debt was incurred as follows:

 

  (i)

in respect of principal payments, based on the Amortization Schedule or other principal repayment requirements applicable under the applicable Facility Agreement;

 

-7-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

in respect of interest payments, in accordance with the provisions of the applicable Facility Agreement;

 

  (iii)

in respect of Permitted Senior Debt Hedging Liabilities, in accordance with the provisions of the applicable Permitted Senior Debt Hedging Instrument; and

 

  (iv)

in respect of all other Senior Debt Obligations, in accordance with the applicable Senior Debt Instrument and the Finance Documents.

 

  (e)

The Borrower shall repay on the Final Maturity Date set forth under each Facility Agreement the full amount of the Loans then outstanding under each such Facility Agreement.

 

  (f)

If any payment due under a Loan or any other amount owed to any Facility Lender falls due on a day which is not a “business day” under the terms of the applicable Facility Agreement, the due date for such payment shall be determined in accordance with the terms of such Facility Agreement, except in the case of the Final Maturity Date under a Facility Agreement, in which case the due date for such payment with respect to such Facility Agreement shall be the immediately preceding Business Day; provided, in each case, that if the due date for any payment under a Loan is extended or shortened as a result of such determination, such extended or shortened period, as the case may be, shall be used in the computation of the amount of interest owed on such extended or shortened due date.

 

  3.2

Right of Repayment and Cancellation in Relation to a Single Facility Lender

 

  (a)

Except as otherwise provided in the relevant Facility Agreement, if any of the circumstances in Section 19.5(c) (Mitigation Obligations; Replacement of Lenders) occurs (other than an Illegality Event, which is addressed under Section 3.4(a)(vi) (Mandatory Prepayments—Illegality)), the Borrower shall have the right (but not the obligation) to give the Intercreditor Agent and the relevant Facility Lender at least three Business Days’ written notice of its intention to cancel the Facility Debt Commitments and repay the Loans of the Facility Lender affected by the relevant circumstance.

 

  (b)

On receipt of a notice referred to in clause (a) above:

 

  (i)

the Facility Debt Commitment of such Facility Lender shall immediately be reduced to zero; and

 

-8-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

the Borrower shall, subject to Section 3.5(c) (Voluntary Prepayments) repay (on a non-pro rata basis) all Senior Debt Obligations owed to such Facility Lender on the last day of the Relevant Interest Period which ends after the Borrower has given notice under clause (a) above (or, if earlier, the date specified by the Borrower in such notice or as required by law).

 

  (c)

Such repayment may be made with the proceeds of Replacement Debt incurred in accordance with Section 6.3 (Replacement Debt) or with other funds then available to the Borrower and permitted under the Finance Documents to be used for such purpose.

 

  3.3

No Repayments or Prepayments

No repayments or prepayments of any Loan may be made other than the repayments or prepayments expressly required or permitted by this Article 3 (Repayment, Prepayment and Cancellation) and, with respect to each Loan, the applicable Facility Agreement.

 

  3.4

Mandatory Prepayments

 

  (a)

Except in the following circumstances, no mandatory prepayments of the Loans are required to be made by the Borrower.

 

  (i)

Insurance and Condemnation Proceeds

The Borrower shall make any prepayments of the Loans required to be made with respect to certain Insurance Proceeds and Condemnation Proceeds in accordance with Section 5.2 (Insurance and Condemnation Proceeds) of the Common Security and Account Agreement.

 

  (ii)

Performance Liquidated Damages

Any Performance Liquidated Damages in excess of $20 million (in the aggregate across all Material Construction Contracts) that are paid to any Obligor pursuant to a Material Construction Contract shall be deposited into the Additional Proceeds Prepayment Account(s) and applied by the Borrower to make prepayments of the Loans, except to the extent such amounts are applied to:

 

  (A)

complete or repair the Project Facilities in respect of which the Performance Liquidated Damages were paid or to pay Project Costs in respect of the Project Facilities within 180 days following receipt thereof (or 270 days if a commitment to complete or repair such Project Facilities or to pay such Project Costs is entered into within 180 days following the receipt of such proceeds); or

 

-9-

Plaquemines – Amended & Restated Common Terms Agreement


  (B)

repay or reimburse providers of Equity Funding to the extent such Equity Funding was used to complete or repair the Project Facilities in respect of which the Performance Liquidated Damages were paid or to pay Project Costs in respect of the Project Facilities; provided that, in no event shall any Equity Contribution be repaid or reimbursed pursuant to this clause (B).

 

  (iii)

LNG SPA Prepayment Events

The Borrower shall make prepayments (if any) of Loans and cancel Senior Debt Commitments as may be required upon the occurrence of an LNG SPA Prepayment Event in accordance with Section 8.2 (LNG SPA Mandatory Prepayment).

 

  (iv)

Termination Payments

In the event that the Borrower receives any termination payments or proceeds in connection with the termination of any Material Project Agreement, such amounts shall be deposited into the Additional Proceeds Prepayment Account(s) to make prepayments of the Loans, except to the extent such amounts are applied to any Replacement Material Contract within 60 days following termination of such Material Project Agreement.

 

  (v)

Net Cash Proceeds from the Sale of Project Property

To the extent that Net Cash Proceeds are received by an Obligor from the sale of Project Property (other than asset sales permitted under Section 12.17 (Sale of Project Property)), and those Net Cash Proceeds are not used to purchase replacement assets within 180 days following receipt thereof (or 270 days if a commitment to purchase replacement assets is entered into within 180 days following the receipt of such proceeds), the Borrower shall make prepayments of the Loans in the amount of those unused proceeds.

 

  (vi)

Illegality

Except as otherwise provided in a Facility Agreement in respect of Advances based on SOFR, upon the Intercreditor Agent providing notice to the Borrower of an Illegality Event with respect to a Facility Lender (together with the related information about such illegality described in Section 19.5 (Mitigation Obligations; Replacement of Lenders)), and subject to Section 19.5 (Mitigation Obligations; Replacement of Lenders):

 

-10-

Plaquemines – Amended & Restated Common Terms Agreement


  (A)

the Facility Debt Commitment of such Facility Lender shall be suspended until such date during the applicable Availability Period that such Facility Lender notifies its Facility Agent that the circumstances giving rise to such determination no longer exist; provided that if the Borrower notifies the affected Facility Lender and the Intercreditor Agent that it intends to exercise its rights under Section 19.5 (Mitigation Obligations; Replacement of Lenders) to require an assignment of the Facility Lender’s rights, interests and commitments as a result of the Illegality Event, the Facility Debt Commitments of such Facility Lender shall be transferred to the assignee Facility Lender and not suspended as set forth herein; and

 

  (B)

the Borrower shall repay any principal and interest outstanding in respect of such Facility Lender’s Loans on the earlier of:

 

  (1)

the next succeeding Quarterly Payment Date falling at least 60 days after the date on which the Intercreditor Agent has provided such notice to the Borrower; and

 

  (2)

the date (if any) required under applicable law.

For the avoidance of doubt, the Borrower may also require the Facility Lender to assign its rights, interests and obligations in accordance with Section 19.5 (Mitigation Obligations; Replacement of Lenders) upon the occurrence of an Illegality Event, which assignment shall extinguish the need for this mandatory prepayment if it occurs prior to the date such mandatory prepayment is required to have occurred.

 

  (vii)

Restricted Payments

Except if a Loan Facility Declared Default has occurred and is Continuing following the delivery of the notice provided under Section 4.6(b) (Control and Investment of Funds in Accounts) of the Common Security and Account Agreement (in which case the cash waterfall provided in Section 4.8 (Accounts During the Continuance of a Declared Event of Default) of the Common Security and Account Agreement shall apply), if, at any time after the end of the quarter in which the Project Phase 2 Completion Date occurs, the Borrower has not met the conditions to make a Restricted Payment pursuant to Section 11.1 (Conditions to Restricted Payments) for

 

-11-

Plaquemines – Amended & Restated Common Terms Agreement


four consecutive quarters (other than as a result of a failure to meet the condition in Section 11.1(f) (Conditions to Restricted Payments), which is addressed instead by the mandatory prepayment in sub-clause (iii) (LNG SPA Prepayment Events) above), but solely to the extent such mandatory prepayment was in fact made in connection with such event, and for as long as such failure to meet such conditions is continuing, on each Quarterly Payment Date during such period the Borrower shall make a mandatory prepayment with the amount that (x) has been unavailable for a Restricted Payment for four consecutive fiscal quarters and (y) would otherwise have been available for a Restricted Payment in accordance with Section 4.5(n)(ii) (Deposits and Withdrawals – Distribution Account) of the Common Security and Account Agreement less any amounts reasonably estimated to be due and payable at any higher level of the cash waterfall within the 30 days following such Quarterly Payment Date.

 

  (viii)

Letters of Credit

 

  (A)

To the extent that the Senior Facilities Debt Service Reserve Account is funded with the proceeds of any Term Loans on the Project Phase 1 Completion Date and thereafter such amount is replaced by an Acceptable Debt Service Reserve LC, the Borrower shall make prepayments of the Term Loans in an amount equal to the lesser of (x) the face amount of the Acceptable Debt Service Reserve LC credited to the Senior Facilities Debt Service Reserve Account and (y) the amount of cash on deposit in the Senior Facilities Debt Service Reserve Account; provided that such amount shall not exceed the aggregate amount of proceeds of Term Loans deposited into the Senior Facilities Debt Service Reserve Account on the Project Phase 1 Completion Date; provided further that such amount shall not exceed the Senior Facilities Reserve Amount.

 

  (B)

To the extent that the Senior Facilities Debt Service Reserve Account is funded with the proceeds of the Construction Account on the Project Phase 2 Completion Date pursuant to Section 14.4(c)(D) (Project Phase 2 Completion Date Waterfall) and thereafter such amount is replaced by an Acceptable Debt Service Reserve LC, the Borrower shall make prepayments of the Term Loans in an amount equal to the lesser of (x) the face amount of the Acceptable Debt Service Reserve LC credited to the Senior Facilities Debt Service Reserve Account and (y) the amount of cash on

 

-12-

Plaquemines – Amended & Restated Common Terms Agreement


  deposit in the Senior Facilities Debt Service Reserve Account; provided that such amount shall not exceed the lesser of (A) the aggregate amount of proceeds of Term Loans (but not Pre-Completion Revenues) transferred to the Senior Facilities Debt Service Reserve Account pursuant to Section 14.4(c)(D) (Project Phase 2 Completion Date Waterfall) and (B) the difference (which shall not be less than zero), between (x) the aggregate amount of the Term Loans that have been funded in respect of the Contingency Reserve Term Loan Commitments under the Credit Facility Agreement (regardless of whether any or all of such Term Loans remain outstanding at such time) and (y) the amount of the prepayment made pursuant to Section 14.4(c)(E) (Project Phase 2 Completion Date Waterfall); provided further that such amount shall not exceed the Senior Facilities Reserve Amount.

 

  (ix)

Contingency Reserve Amount

 

  (A)

[reserved].

 

  (B)

On the Project Phase 2 Completion Date, the Borrower shall make a prepayment of the Term Loans as specified in Section 14.4(c)(E) (Project Phase 2 Completion Date Waterfall).

 

  (x)

Replacement Debt

The Borrower shall use the proceeds of any Replacement Debt (after accounting for any related Hedging Termination Amount and related fees and expenses) to prepay or repay Senior Debt and/or replace all or part of the Facility Debt Commitments in accordance with Section 6.3 (Replacement Debt).

 

  (b)

Mandatory prepayments to Facility Lenders will be made with accrued interest on the amount so prepaid, and upon not less than three Business Days’ prior written notice to each Facility Agent.

 

  (c)

Except as provided in Section 3.7 (Pro Rata Payment), mandatory prepayments will be applied first, pro rata among each Senior Creditor Group under this Agreement (and in the case of outstanding Term Loans, pro rata, without regard to whether such Term Loans are Initial Senior Debt or Incremental Senior Debt) based on the Loans outstanding on the date of such prepayment, and second, pro rata to the cash collateralization of any outstanding Letters of Credit.

 

-13-

Plaquemines – Amended & Restated Common Terms Agreement


  (d)

Except for a mandatory prepayment in accordance with sub-clause 3.4(a)(ii) (Mandatory Prepayments – Performance Liquidated Damages), 3.4(a)(viii) (Mandatory Prepayments – Letters of Credit) above and/or incurrence of Replacement Debt pursuant to Section 6.3 (Replacement Debt) below, which shall be applied pro rata against subsequent scheduled payments, all mandatory prepayments under this Section 3.4 (Mandatory Prepayments) shall be paid and applied in inverse order of maturity.

 

  3.5

Voluntary Prepayments

 

  (a)

Except as otherwise provided in any applicable Facility Agreement with respect to voluntary prepayments, the Borrower shall have the right, upon not less than three Business Days’ prior written notice to the Intercreditor Agent and each Facility Agent and, to the extent such voluntary prepayment is to be made with the net proceeds received in respect of any Replacement Debt, upon delivery of the certifications required pursuant to Section 6.3 (Replacement Debt) with the advanced notice contemplated therein to the Intercreditor Agent and each Facility Agent, to make voluntary prepayments of Loans, in multiples of $1,000,000, or in such other amounts related to the net proceeds received in respect of any Replacement Debt, in each case either in whole or in part, at any time.

 

  (b)

Each notice of voluntary prepayment shall be irrevocable, except that a notice of voluntary prepayment may state that such notice is conditioned upon the effectiveness of other credit facilities or debt instruments in respect of Replacement Debt, in which case such notice may be revoked by the Borrower (by written notice to the Intercreditor Agent and each Facility Agent on or prior to the specified effective date) if such condition is not satisfied. Within 30 days after the revocation of the notice of voluntary prepayment in accordance with the provisions of this clause (b), the Borrower shall pay any Funding Losses incurred by any Facility Lender as a result of such notice and revocation.

 

  (c)

In the case of a partial voluntary prepayment, the Borrower may not make such voluntary prepayment with respect to Term Loans (i) prior to the Project Phase 1 Completion Date unless it certifies to the Intercreditor Agent (and the Independent Engineer concurs with such certification in writing; provided that no such confirmation will be required for any reduction with respect to any Replacement Debt) that such voluntary prepayment will not result in the Obligors’ having an insufficient amount of committed or funded capital (on the basis of all other available funds, including funds in the Construction Account, remaining Facility Debt Commitments and/or the proceeds of any Replacement Debt to be deposited into the Construction Account concurrently with such cancellation) to fund the remaining expenditures required to achieve the Project Phase 1

 

-14-

Plaquemines – Amended & Restated Common Terms Agreement


Completion Date by the Phase 1 LNG Facility Date Certain or the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain, in accordance with the Construction Budget and Schedule, or (ii) after the Project Phase 1 Completion Date and prior to the Project Phase 2 Completion Date unless it certifies to the Intercreditor Agent (and the Independent Engineer concurs with such certification in writing; provided that no such confirmation will be required for any reduction with respect to any Replacement Debt) that such voluntary prepayment will not result in the Obligors’ having an insufficient amount of committed or funded capital (on the basis of all other available funds, including funds in the Construction Account, remaining Facility Debt Commitments and/or the proceeds of any Replacement Debt to be deposited into the Construction Account concurrently with such cancellation) to fund the remaining expenditures required to achieve the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain, in accordance with the Construction Budget and Schedule.

 

  (d)

Except as provided in Section 3.7 (Pro Rata Payment), voluntary prepayments will be applied pro rata among each Senior Creditor Group under this Agreement (and in the case of outstanding Term Loans, pro rata, without regard to whether such Term Loans are Initial Senior Debt or Incremental Senior Debt except as otherwise provided in the Credit Facility Agreement) based on the Loans outstanding on the date of such prepayment and otherwise as directed by the Borrower.

 

  3.6

Prepayment Fees and Funding Losses

Any prepayment (whether a mandatory prepayment or voluntary prepayment) of Loans or cancellation of Facility Debt Commitments, including prepayments or cancellations made in accordance with this Article 3 (Repayment, Prepayment and Cancellation), Section 6.3 (Replacement Debt) or Section 19.5 (Mitigation Obligations; Replacement of Lenders) shall, in each case, be made without any prepayment charges, fees, premium, penalty or other charges other than (a) Funding Losses incurred (if any are required to be paid pursuant to the terms of the applicable Facility Agreement) and (b) prepayment fees, premia, penalties or charges specified in any Facility Agreement, including for Working Capital Debt. Unless otherwise specified in an individual Facility Agreement, Funding Losses (if any) with respect to any prepayment shall be payable only if such prepayment is made on a date other than a CTA Payment Date.

 

  3.7

Pro Rata Payment

Except as specified in Section 6.3(a)(viii) (Replacement Debt) or to the extent that any Facility Lender waives or declines receipt of its Pro Rata Payment of any prepayment in accordance with the terms of any Senior Debt Instrument to which

 

-15-

Plaquemines – Amended & Restated Common Terms Agreement


it is a party, at any time the Borrower makes a payment or prepayment in whole or in part of the Senior Debt Obligations owed to one or more Facility Lenders, the Borrower shall make a Pro Rata Payment to all other Facility Lenders (and in the case of outstanding Term Loans, pro rata); provided that:

 

  (a)

except as otherwise provided in any individual Facility Agreement, the mandatory prepayments described in Section 3.4(a)(vi) (Mandatory Prepayments – Illegality) will be applied pro rata only to the affected Loans and not pro rata to each Loan;

 

  (b)

(i) a voluntary prepayment of Loans made under the Credit Facility Agreement or any other Facility Agreement for Loans that are not Working Capital Debt may be made without a pro rata repayment of Loans under any Facility Agreement for Working Capital Debt (and, conversely, a voluntary prepayment of Loans under any Facility Agreement for Working Capital Debt may be made without a voluntary prepayment of Loans under any other Facility Agreement) and (ii) only the mandatory prepayments set forth in Section 3.4(a)(iii) (Mandatory Prepayments LNG SPA Prepayment Events) (but only to the extent set forth in, and subject to the requirements of, Section 8.2 (LNG SPA Mandatory Prepayment)) will be applied pro rata with respect to any Working Capital Debt; and

 

  (c)

the following prepayments will not be subject to the pro rata payment requirement:

 

  (i)

a voluntary or mandatory prepayment of Loans to Facility Lenders under a Facility Agreement, whose Loans thereunder have been amended and extended in accordance with its terms, to the extent such Facility Lenders have agreed to a non pro rata prepayment, in which case prepayments to such Facility Lenders shall be made on the basis set forth in the relevant Facility Agreement, as amended and extended, in accordance with the terms of such agreement;

 

  (ii)

a voluntary prepayment of Loans to only certain affected Facility Lenders or only Facility Lenders under certain affected Facility Agreements made pursuant to Section 3.2 (Right of Repayment and Cancellation in Relation to a Single Facility Lender) or Section 19.5 (Mitigation Obligations; Replacement of Lenders) or comparable provisions to those described in Section 3.2 (Right of Repayment and Cancellation in Relation to a Single Facility Lender) or Section 19.5 (Mitigation Obligations; Replacement of Lenders) under a Facility Agreement;

 

-16-

Plaquemines – Amended & Restated Common Terms Agreement


  (iii)

a voluntary prepayment that is financed with proceeds of Replacement Debt; provided that such prepayment will be pro rata across all then-outstanding Loans, including, with respect to Term Loans under the Credit Facility Agreement, without regard to whether such Term Loans are Initial Senior Debt or Incremental Senior Debt (other than Working Capital Debt), except as otherwise required by Section 6.3(a)(i)(C) (Replacement Debt); and

 

  (iv)

a payment or prepayment to a Senior Creditor if such payment or prepayment is made in the applicable circumstances set forth in sub- clauses (B), (C), (D) and (E) of Section 2.3(a)(ii) (Payments and Prepayments – Pro Rata Payment of Senior Debt Obligations) of the Common Security and Account Agreement.

 

  3.8

Reductions and Cancellations of Facility Debt Commitments

 

  (a)

The Borrower may cancel Facility Debt Commitments, in whole or in part, in multiples of $5,000,000, pro rata among each Facility Lender (and in the case of the Credit Facility Agreement, without regard to whether such Facility Debt Commitments were made pursuant to the Original Credit Facility Agreement or the Credit Facility Agreement) (except, in each case, in the case of a cancellation of Facility Debt Commitments in accordance with the Facility Agreement, as specified in Section 6.3(a)(viii) (Replacement Debt) or otherwise in the case where the Borrower is entitled to make a non-pro rata cancellation or prepayment pursuant to Section 3.2 (Right of Repayment and Cancellation in Relation to a Single Facility Lender) and Section 3.7 (Pro Rata Payment)), subject to any minimum cancellation amounts required under the Facility Agreement, by giving at least three Business Days’ prior written notice to the Intercreditor Agent and the applicable Facility Agent or such other notice period required under the applicable Facility Agreement; provided that a notice of cancellation may state that such notice is conditioned upon the effectiveness of other credit facilities or debt instruments in respect of Replacement Debt, in which case such notice may be revoked by the Borrower (by written notice to the Intercreditor Agent and the applicable Facility Agent on or prior to the specified effective date) if such condition is not satisfied.

 

  (b)

Within 30 days of the date of the notice of cancellation delivered in accordance with sub-clause (a) above, the Borrower shall pay any Funding Losses incurred by any Facility Lender as a result of such notice and revocation.

 

  (c)

The Borrower may not make a voluntary cancellation under this Section 3.8 (Reductions and Cancellations of Facility Debt Commitments) with respect to the Term Loan Commitments (i) prior to the Project Phase 1 Completion Date unless it certifies to the Intercreditor Agent (and the Independent Engineer concurs with such certification in writing; provided that no such

 

-17-

Plaquemines – Amended & Restated Common Terms Agreement


  confirmation will be required for any cancellation with respect to any Replacement Debt) that such voluntary cancellation shall not result in the Obligors’ having an insufficient amount of funded or committed capital (on the basis of all other available funds, including funds in the Construction Account, remaining Term Loan Commitments and/or the proceeds of any Replacement Debt to be deposited into the Construction Account concurrently with such cancellation) to fund the remaining expenditures required in order to achieve the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain or the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain in accordance with the Construction Budget and Schedule or (ii) after the Project Phase 1 Completion Date and prior to the Project Phase 2 Completion Date unless it certifies to the Intercreditor Agent (and the Independent Engineer concurs with such certification in writing; provided that no such confirmation will be required for any cancellation with respect to any Replacement Debt) that such voluntary cancellation will not result in the Obligors’ having an insufficient amount of committed or funded capital (on the basis of all other available funds, including funds in the Construction Account, remaining Term Loan Commitments and/or the proceeds of any Replacement Debt to be deposited into the Construction Account concurrently with such cancellation) to fund the remaining expenditures required to achieve the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain, in accordance with the Construction Budget and Schedule.

 

  (d)

Notwithstanding anything in this Section 3.8 (Reductions and Cancellations of Facility Debt Commitments) to the contrary, the procedure for cancellation related to a mandatory prepayment pursuant to Section 3.4 (Mandatory Prepayments) shall be subject to the terms of the applicable mandatory prepayment in Section 3.4 (Mandatory Prepayments) or elsewhere in the Finance Documents and not this Section 3.8 (Reductions and Cancellations of Facility Debt Commitments).

 

  3.9

Late Payments

Except as otherwise provided under any Facility Agreement, if any amounts required to be paid by the Borrower under this Agreement or the other Finance Documents (including principal or interest payable on any disbursement and any fees and other amounts otherwise payable to any Secured Party) remain unpaid after such amounts are due (whether at stated maturity, by acceleration or otherwise), the Borrower shall pay interest on the overdue amount (including, to the extent allowable under applicable law, on overdue interest) from the date due until such past due amounts are paid in full at a per annum rate equal to the Default Rate and such interest shall be payable on demand.

 

-18-

Plaquemines – Amended & Restated Common Terms Agreement


  3.10

No Borrowing or Reinstatement

No amounts of Loans which have been cancelled, repaid or prepaid in accordance with this Article 3 (Repayment, Prepayment and Cancellation) and the relevant Facility Agreement may be reborrowed; provided that Working Capital Debt may be repaid and reborrowed in accordance with the terms of its applicable Facility Agreement.

 

4.

CONDITIONS PRECEDENT

 

  4.1

Conditions to Initial Closing Date and Initial Advance

The Initial Closing and the obligation of each Facility Lender to make available its Initial Advance shall be subject to the satisfaction or waiver by each of the Facility Lenders of each of the following, and no other, common conditions precedent, in each case in form and substance reasonably satisfactory to, each of the Facility Lenders, and, where applicable, with sufficient copies for, each Facility Agent acting on the instructions of the Facility Lenders under the applicable Facility Agreement:

 

  (a)

Execution and Delivery of the Finance Documents. Receipt by the Facility Lenders, Collateral Agent and the Intercreditor Agent of true, complete and correct copies of the Original Finance Documents (other than Direct Agreements, which are addressed in clause (b) (Delivery of Material Project Agreements; Direct Agreements) below) and by the Account Bank of the Original Common Security and Account Agreement, executed and delivered by the parties thereto;

 

  (b)

Delivery of Material Project Agreements; Direct Agreements. Receipt by the Facility Lenders and the Intercreditor Agent of:

 

  (i)

the Phase 1 Initial LNG SPAs, under which, in respect of the Qualifying LNG SPAs, LNG Buyers have committed to purchase a quantity of LNG equal to not less than the Base Committed Quantity as described in clause (a) of the definition thereof and subject to the DPU LNG SPA Quantity Restrictions, each of which shall have been duly authorized, executed and delivered by the parties thereto; and

 

  (A)

as to which, in respect of the Qualifying LNG SPAs, (1) all conditions precedent thereunder shall have been satisfied or waived by or concurrently with the CP Satisfaction Date, (2) the CP Satisfaction Date shall occur on or prior to the date of the Initial Advance, (3) no event of LNG SPA Force Majeure shall have occurred and be continuing and (4) no default, event of default or other event or condition shall have occurred and be continuing that provides the applicable LNG Buyer the right to cancel or terminate such Qualifying LNG SPA in accordance with the terms thereof;

 

-19-

Plaquemines – Amended & Restated Common Terms Agreement


  (B)

a certificate of the Obligor that is party to such agreement certifying that (1) the copy of such agreement provided to the Facility Lenders is a true, correct and complete copy of such document, and (2) such agreement is in full force and effect and no term or condition of such agreement has been amended from the form thereof delivered to the Facility Lenders prior to the Initial Closing Date (other than amendments in accordance with the Finance Documents and provided to the Intercreditor Agent); and

 

  (C)

with respect to any Qualifying LNG SPA, a Direct Agreement, substantially in the form attached as Schedule G (Forms of Direct Agreement) of the Original Common Security and Account Agreement (or otherwise reasonably acceptable to the Facility Lenders);

 

  (ii)

with respect to each Phase 1 Material Project Agreement (including the Phase 1 Excess Capacity LNG SPA and other than any Subsequent Material Project Agreement or any Replacement Material Contract and other than as provided in sub-clause (i) above with respect to the LNG SPAs):

 

  (A)

a copy of such agreement (other than any Restricted Document which shall be delivered in accordance with the requirements of Section 12.6(c) (Confidentiality) of the Original Common Security and Account Agreement and Section 23.7 (Confidentiality) of the Original Common Terms Agreement), which shall have been duly authorized, executed and delivered by the parties thereto, as to which no force majeure event (as defined in each such Phase 1 Material Project Agreement) has occurred and is continuing except as set forth on Schedule H (Material Project Agreements and Certain Other Contracts) of the Original Common Terms Agreement;

 

  (B)

a certificate of the Obligor that is party to such agreement certifying that (1) the copy of such agreement provided to the Facility Lenders is a true, correct and complete copy of such document, and (2) such agreement is in full force and effect and no term or condition of such agreement has been amended from the last form thereof delivered to the Facility Lenders prior to the Initial Closing Date (other than amendments in accordance with the Finance Documents and provided to the Intercreditor Agent); and

 

-20-

Plaquemines – Amended & Restated Common Terms Agreement


  (C)

a Direct Agreement, either substantially in the form attached as Schedule G (Forms of Direct Agreement) of the Original Common Security and Account Agreement (or otherwise reasonably acceptable to the Collateral Agent), with each counterparty to such agreement, to the extent such Direct Agreement is required to be delivered by the Initial Closing Date pursuant to Section 3.4 (Direct Agreements) of the Original Common Security and Account Agreement;

 

  (iii)

with respect to each Site Works Contract, a notice of collateral assignment reasonably acceptable to the Collateral Agent, delivered to each counterparty to a Site Works Contract and to Keller Holdings, Inc.;

 

  (iv)

with respect to each Phase 1 Material Project Agreement (other than any Subsequent Material Project Agreement or any Replacement Material Contract), a copy of all performance security, letters of credit and guarantees (A) required to be delivered under each Phase 1 Material Project Agreement by the Phase 1 Material Project Counterparties as of the Initial Closing Date and (B) delivered by one or more parent companies of the Pledgor to Phase 1 Material Project Counterparties (all of which, for the avoidance of doubt, will be replaced by Letters of Credit following the Initial Closing) and a certificate of each Obligor that copies of all such performance security, letters of credit and guarantees required to be delivered pursuant to this clause (iv) have been provided to the Facility Lenders; and

 

  (v)

all Phase 1 Material Project Agreements (or any amendments thereto) that were made available for viewing to the Facility Lenders after the date of the Initial Commitment Letter shall be in form and substance satisfactory to the Facility Lenders.

 

  (c)

Material Project Agreement Default. As of the Initial Closing Date, no material default or event of default of any Obligor, and to the Knowledge of each Obligor, no material default or event of default of any counterparty exists under any Phase 1 Material Project Agreement;

 

-21-

Plaquemines – Amended & Restated Common Terms Agreement


  (d)

FERC Order. The FERC Order:

 

  (i)

has been obtained by the Borrower with respect to the LNG Facility and by the Guarantor with respect to the Gator Express Pipeline;

 

  (ii)

is in full force and effect;

 

  (iii)

is final and non-appealable; and

 

  (iv)

is free from conditions and requirements:

 

  (A)

the compliance with which could reasonably be expected to have a Material Adverse Effect; or

 

  (B)

that the applicable Obligor does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Project Phase 1 Development except to the extent that failure to satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect;

 

  (e)

Export Authorizations. Each of the FTA Authorization and the Non-FTA Authorization:

 

  (i)

has been obtained by the Borrower;

 

  (ii)

is in full force and effect;

 

  (iii)

is free from conditions or requirements:

 

  (A)

the compliance with which could reasonably be expected to have a Material Adverse Effect; or

 

  (B)

that the Borrower does not expect to be able to satisfy on or prior to the commencement of the relevant stage of the Project Phase 1 Development except to the extent that failure to so satisfy such condition could not reasonably be expected to have a Material Adverse Effect;

 

  (f)

Opinions from Counsel. Receipt by the Intercreditor Agent and the Credit Facility Secured Parties of the legal opinions and reliance letters set forth in Schedule C-1 (Table of Requirements for Legal Opinions – Conditions to Initial Closing) of the Original Common Terms Agreement and in accordance with the requirements therein, with such changes thereto as may be in form and substance reasonably satisfactory to the Intercreditor Agent;

 

-22-

Plaquemines – Amended & Restated Common Terms Agreement


  (g)

Project Development. Receipt by the Intercreditor Agent of true, complete and correct copies of:

 

  (i)

a certificate of the Obligors attaching the Construction Budget and Schedule with respect to the Project Phase 1 Development, substantially in the form attached as Schedule D–1 (Construction Budget and Schedule – Construction Budget) and Schedule D—2 (Construction Budget and Schedule – Construction Schedule) of the Original Common Terms Agreement, which shall include a list or schedule of the amount of Project Costs paid by the Obligors prior to the Initial Closing Date, and certifying that: (A) such budget and schedule is the best reasonable estimate of the information set forth therein as of the date of such certificate; and (B) such budget and schedule is based on assumptions made in good faith and believed reasonable at the time made in light of the legal and factual circumstances then applicable to the Project Phase 1 Development and is consistent with the requirements of the Transaction Documents as of the Initial Closing Date;

 

  (ii)

a certificate of the Obligors attaching the Base Case Forecast as of the Initial Closing Date, which demonstrates compliance with the Base Case Sizing Criteria as of the Initial Closing Date, and certifying that: (A) the projections in the Base Case Forecast were made in good faith; and (B) the assumptions on the basis of which such projections were made were believed by the Borrower (when made and delivered) to be reasonable and consistent with the Construction Budget and Schedule and the Transaction Documents as of the Initial Closing Date;

 

  (iii)

a final report of the Independent Engineer (including certifications and discussions therein relating to the adequacy of the contingency relating to the Project to satisfy potential cost overruns with respect to the Project Phase 1 Development), together with a reliance letter from the Independent Engineer in form and substance reasonably satisfactory to the Credit Facility Agent;

 

  (iv)

a final report of the CCRA Consultant, together with a reliance letter from the CCRA Consultant in form and substance reasonably satisfactory to the Credit Facility Agent;

 

  (v)

a final report prepared by the Market Consultant, together with a reliance letter from the Market Consultant in form and substance reasonably satisfactory to the Credit Facility Agent;

 

-23-

Plaquemines – Amended & Restated Common Terms Agreement


  (vi)

final reports prepared by the Environmental Consultants, described on Schedule X (Phase I Environmental Assessments) of the Original Common Terms Agreement, together with a reliance letter from each Environmental Consultant, each in form and substance reasonably satisfactory to the Credit Facility Agent; and

 

  (vii)

a certificate of the Independent Engineer (A) concurring with the Borrower’s certification in sub-clause (i) above and (B) validating the Obligors’ list or schedule of the amount of Project Costs paid by the Borrower prior to the Initial Closing Date referred to in sub- clause (i) above;

 

  (h)

Financial Statements. Receipt by the Intercreditor Agent of:

 

  (i)

a certified copy of the most recent pro forma balance sheet of each Obligor; and

 

  (ii)

to the extent delivered to the Borrower or the Guarantor under any Phase 1 Material Project Agreement, financial statements of the Phase 1 Material Project Counterparties;

 

  (i)

Insurance. Receipt by the Intercreditor Agent of:

 

  (i)

a report from the Insurance Advisor, prepared in accordance with generally accepted consulting practices together with a certificate of the Insurance Advisor confirming that the insurance policies to be provided in compliance with Section 12.28 (Insurance Covenant) of the Original Common Terms Agreement conform to the requirements specified in the Finance Documents and are in accordance with Prudent Industry Practices; and

 

  (ii)

a reliance letter from the Insurance Advisor in form and substance reasonably satisfactory to the Credit Facility Agent;

 

  (j)

Real Property.

 

  (i)

Receipt by the Collateral Agent of (A) a Survey and (B) a Title Policy (with respect only to the LNG Facility Site and not the laydown lease) conforming to the requirements specified in the definition of each such term; and

 

  (ii)

Receipt by the Collateral Agent of: (A) an estoppel certificate from the lessor for the Lease described in clause (a) of the definition of “Leases” that includes a consent in respect of the Access License Agreement described in clause (a) of the definition of “Access License Agreements”; and (B) an estoppel certificate from the lessor for the Lease described in clause (b) of the definition of “Leases”.

 

-24-

Plaquemines – Amended & Restated Common Terms Agreement


  (k)

Bank Regulatory Requirements. Receipt by the Intercreditor Agent and each other Finance Party that is a party to this Agreement:

 

  (i)

at least three Business Days prior to the Initial Closing Date, with respect to each of the Collateral Parties, of a certified electronic copy of each of the documents listed in Schedule E (Know Your Customer Documentation) of the Original Common Terms Agreement that are required in order for each Facility Lender to carry out all necessary “know your customer” or similar requirements and such other information as may be reasonably required by such Facility Lender to address such requirement, including those reasonably required to ensure compliance with anti-money laundering procedures (including the USA Patriot Act) in its relevant jurisdiction, in each case to the extent not otherwise delivered to the relevant Finance Party at or prior to the Initial Closing Date (and provided that any subsequent changes in such documents or updates to information contained therein shall be so delivered in accordance with this clause (k)(i)); and

 

  (ii)

at least three Business Days prior to the Initial Closing Date, a Beneficial Ownership Certification from the Borrower if it qualifies as a “legal entity customer” under the Beneficial Ownership Regulation;

 

  (l)

Officer’s Certificates. Receipt by the Intercreditor Agent of a copy of a duly executed certificate of each of the Collateral Parties and, with respect to sub-clauses (i)–(iii) below, of each Affiliated Service Counterparty:

 

  (i)

attaching a copy of the Constitutional Documents of each of the Collateral Parties and each Affiliated Service Counterparty, together with any amendments thereto (and certifying that such Constitutional Documents have not been revoked or amended since the date of the attached Constitutional Documents);

 

  (ii)

attaching copies of resolutions approving the Collateral Parties’ and the Affiliated Service Counterparties’ entry into the Finance Documents and Phase 1 Material Project Agreements, as applicable (and certifying that such resolutions have not been revoked or amended since the date of adoption thereof);

 

  (iii)

attaching incumbency certificates in respect of signatories; and

 

-25-

Plaquemines – Amended & Restated Common Terms Agreement


  (iv)

certifying that the conditions in clauses (c) (Material Project Agreement Default) and (m) (Representations and Warranties) of this Section 4.1 (Conditions to Initial Closing Date and Initial Advance) have been met;

 

  (m)

Representations and Warranties. Each of the representations and warranties of the Obligors as set forth under Article 5 (Representations and Warranties of the Obligors) of this Agreement is true and correct in all material respects (except for those qualified by materiality, each of which shall be true and correct in all respects) as to such Obligor on and as of the Initial Closing Date as if made on and as of the Initial Closing Date (or if stated to have been made solely as of an earlier date, as of such earlier date);

 

  (n)

Establishment of Accounts. Receipt by the Collateral Agent (with a copy to the Intercreditor Agent) of evidence that each of the Accounts required to be in existence as of the Initial Closing Date has been established as required pursuant to the Original Common Security and Account Agreement;

 

  (o)

Lien Search; Perfection of Security. Receipt by the Collateral Agent of copies or evidence, as the case may be, of the following actions in connection with the perfection of the Collateral:

 

  (i)

completed requests for information or copies of the UCC search reports and tax lien, judgment and litigation search reports for the State of Delaware and the State of Louisiana, and any other jurisdiction reasonably requested by any of the Facility Agents that name each Obligor or the Pledgor as debtor, together with copies of each UCC financing statement, fixture filing or other filings listed therein, which evidences no Liens on the Collateral, other than Permitted Liens; all dated within 15 Business Days prior to the Initial Closing Date;

 

  (ii)

UCC financing statements, fixture filings or other filings reflecting the Liens granted pursuant to the Original Common Security and Account Agreement and the other Security Documents that any of the Facility Agents may deem necessary or desirable in order to perfect the first priority Liens (subject to Permitted Liens) created thereunder; and

 

  (iii)

the Collateral is subject to the perfected first priority Lien (subject only to Permitted Liens) established pursuant to the Security Documents;

 

-26-

Plaquemines – Amended & Restated Common Terms Agreement


  (p)

Fees; Expenses. Irrevocable instructions for the payment to each of the Facility Agents for its own account, or for the account of the relevant Facility Lender entitled thereto, of all fees due and payable as of the Initial Closing Date pursuant to the Finance Documents, and all costs and expenses (including reasonable costs, fees and expenses of legal counsel and Consultants) payable thereunder for which reasonably detailed invoices have been presented to the Borrower at least three Business Days prior to the Initial Closing Date;

 

  (q)

Authority to Conduct Business. Receipt by the Intercreditor Agent of satisfactory evidence, including certificates of good standing, dated no more than five Business Days prior to the Initial Closing Date, from the Secretary of the State of Louisiana and the Secretary of State of the State of Delaware, as applicable, of the authority of each Collateral Party and Affiliated Service Counterparty to carry on its business;

 

  (r)

Total Capitalization. The aggregate Term Loan Commitments are not more than 75% of the then-current estimate of Project Costs projected in the Construction Budget and Schedule as of the Initial Closing Date to be incurred by the Obligors for the Project Phase 1 Development;

 

  (s)

Lien Waivers. Receipt by the Intercreditor Agent of Lien Waivers as have then been required pursuant to each of the Phase 1 Material Construction Contracts and the Site Works Contracts;

 

  (t)

Flood Insurance. Receipt by each of the Facility Lenders of the following flood coverage documents from the Borrower, in each case to be satisfactory to each of the Facility Lenders:

 

  (i)

a completed “Standard Flood Hazard Determination Form” of the Federal Emergency Management Agency and any successor Governmental Authority performing a similar function (a “Flood Certificate”) with respect to the anticipated real property comprising the LNG Facility Site (including leasehold interests therein) expected to be included in the Collateral (“Mortgaged Property”), which Flood Certificate shall:

 

  (A)

be addressed to the Credit Facility Agent;

 

  (B)

provide for “life of loan” monitoring; and

 

  (C)

otherwise comply with the National Flood Insurance Program created by the US Congress pursuant to the National Flood Insurance Act of 1968, the Flood Disaster Protection Act of 1973, the National Flood Insurance Reform Act of 1994 and the Flood Insurance Reform Act of 2004 and any successor statutes (the “Flood Program”);

 

-27-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

if the Flood Certificate states that any structure comprising a portion of the anticipated Mortgaged Property will be located in a special flood hazard area (as defined pursuant to applicable flood insurance regulations), the Borrower’s written acknowledgment of receipt of written notification from the Credit Facility Agent and any Facility Lender requesting the same:

 

  (A)

as to the existence of such Mortgaged Property; and

 

  (B)

as to whether the community in which such Mortgaged Property will be located is participating in the Flood Program;

 

  (u)

Notes. Receipt of copies of the notes requested by the Facility Lenders pursuant to their Facility Agreement, as applicable, duly authorized, executed and delivered by the Borrower;

 

  (v)

Litigation; Regulatory Action. There are no actions, suits, proceedings, investigations or similar actions pending or, to the knowledge of each Obligor, threatened (in writing) against such Obligor that have had or could reasonably be expected to have a Material Adverse Effect;

 

  (w)

Releases under Bridge Loan.

 

  (i)

Receipt by the Intercreditor Agent of a release letter, in form and substance reasonably satisfactory to the Intercreditor Agent, confirming that all security interests, pledges, encumbrances, and/or other Liens on the Pledgor’s Equity Interests in the Obligors securing the Bridge Loan have been released or shall be released, concurrently with the consummation of the transactions contemplated by the Transaction Documents; and

 

  (ii)

the Obligors shall have repaid, or made arrangements to repay, all outstanding Indebtedness and other obligations incurred and outstanding in connection with the Bridge Loan, substantially concurrently with the Initial Closing Date, in accordance with the Funds Flow Memorandum delivered in accordance with Section 4.1(dd) (Funds Flow Memorandum).

 

  (x)

Assignment of Sponsor Intercompany Loan and Mortgage. Receipt by the Intercreditor Agent of assignment agreements, in form and substance reasonably satisfactory to the Intercreditor Agent, assigning the Sponsor Intercompany Loan to the Credit Facility Agent and assigning the Mortgage to the Collateral Agent, concurrently with the consummation of the transactions contemplated by the Transaction Documents in place as of the Initial Closing Date;

 

-28-

Plaquemines – Amended & Restated Common Terms Agreement


  (y)

No Force Majeure. To the knowledge of the Obligors, no event of force majeure (as defined under the applicable Phase 1 Material Project Agreement) has occurred and is continuing under any Phase 1 Material Project Agreement the consequences of which could reasonably be expected to have a Material Adverse Effect;

 

  (z)

Absence of Default. No Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing on such date or could reasonably be expected to result from the consummation of the transactions contemplated by the Transaction Documents in place as of the Initial Closing Date;

 

  (aa)

Equity Funding Commitments and Minimum Funded Amount.

 

  (i)

The aggregate amount of equity commitment support securing the unfunded amount of equity funding commitments (before giving effect to any Equity Funding as of the Initial Closing Date) is equal to at least $2,000,000,000 and the Intercreditor Agent shall have been provided a copy of each equity commitment document;

 

  (ii)

Plaquemines Holdings shall have indirectly made, or made arrangements to indirectly make, substantially concurrently with the Initial Closing Date, an equity contribution in an amount equal to at least $1,250,000,000 pursuant to an initial equity contribution agreement in accordance with the Funds Flow Memorandum delivered in accordance with Section 4.1(dd) (Funds Flow Memorandum); and

 

  (iii)

the Senior Debt/Equity Ratio shall be no greater than 75:25 after giving effect to any Equity Funding and borrowing of Term Loans on the Initial Closing Date;

 

  (bb)

Notice to Proceed. Issuance by the Borrower and the Guarantor, as applicable, of the “Notice to Proceed” or “FNTP”, as applicable, under and in accordance with each of the Phase 1 Material Construction Contracts;

 

  (cc)

Delivery of Material Permits. The Intercreditor Agent has received a copy of each material Permit (including the FERC Order, the FTA Authorization and Non-FTA Authorization);

 

  (dd)

Funds Flow Memorandum. Delivery by the Borrower of the memorandum setting forth the flow of funds on the Initial Closing Date;

 

-29-

Plaquemines – Amended & Restated Common Terms Agreement


  (ee)

Due Diligence CPs. The Borrower shall have satisfied each of the following conditions:

 

  (i)

the Borrower shall have received written confirmation from BHES that the basis of design of the UOP-delivered pre-treatment systems does not affect any performance guarantee (including any minimum performance guarantee or unconditional performance obligation) under the PIS 2021 Purchase Order, PIS 2022 Purchase Order or Phase 1 LTS Purchase Order; and

 

  (ii)

execution of a Change Order to the Phase 1 EPC Contract resolving the “Open Cost Items” for purposes of the Phase 1 EPC Contract;

 

  (ff)

Equator Principles. Reasonable satisfaction of customary Lender diligence in respect of Equator Principles matters, and implementation (to the extent required as of the Initial Closing Date) in all material respects of the “Equator Principles Action Plan” (as described in the Independent Engineer’s final report); and

 

  (gg)

Insurance. Receipt by each Lender of satisfactory documentary evidence of either (a) the payment of insurance premiums on or before the Initial Closing Date or (b) the concurrent payment on the Initial Closing Date, in each case, sufficient to ensure that the Borrower’s flood insurance policy is in full force and effect as of the Initial Closing Date.

The foregoing conditions were satisfied or waived on, and the Initial Closing Date occurred on, May 25, 2022.

 

  4.2

Conditions to Upsize Closing Date

The Upsize Closing shall be subject to the satisfaction or waiver by each of the Facility Lenders of each of the following, and no other, common conditions precedent, in each case in form and substance reasonably satisfactory to, each of the Facility Lenders, and, where applicable, with sufficient copies for, each Facility Agent acting on the instructions of the Facility Lenders under the applicable Facility Agreement:

 

  (a)

Execution and Delivery of the Finance Documents.

 

  (i)

Receipt by the Facility Lenders, Collateral Agent and the Intercreditor Agent of true, complete and correct copies of the Common Terms Agreement, the Common Security and Account Agreement, the Credit Facility Agreement, the Intercreditor Agreement and the Pledgor Reaffirmation Agreement dated as of the Upsize Closing Date and the other Finance Documents (other

 

-30-

Plaquemines – Amended & Restated Common Terms Agreement


  than Direct Agreements, which are addressed in clause (b) (Delivery of Material Project Agreements; Direct Agreements) below) and by the Account Bank of the Common Security and Account Agreement, executed and delivered by the parties thereto; and

 

  (ii)

Receipt by the Intercreditor Agent of true, complete and correct copies of the Project Phase 2 Development Debt Conditions Satisfaction Notice and Request for Consent evidencing the consent of each Initial Senior Creditor to the incurrence of the Incremental Senior Debt or the replacement of any non-consenting Initial Senior Creditor pursuant to Section 6.4 (Project Phase 2 Development Debt) of the Original Common Terms Agreement;

 

  (b)

Delivery of Material Project Agreements; Direct Agreements. Receipt by the Facility Lenders and the Intercreditor Agent of:

 

  (i)

the LNG SPAs, under which, in respect of the Qualifying LNG SPAs, LNG Buyers have committed to purchase a quantity of LNG equal to not less than the Base Committed Quantity as described in clause (b) of the definition thereof and subject to the DPU LNG SPA Quantity Restrictions, each of which shall have been duly authorized, executed and delivered by the parties thereto; and

 

  (A)

as to which, in respect of the Qualifying LNG SPAs, (1) all conditions precedent thereunder shall have been satisfied or waived by or concurrently with the CP Satisfaction Date, (2) the CP Satisfaction Date shall occur on or prior to the Upsize Closing Date, (3) no event of LNG SPA Force Majeure shall have occurred and be continuing and (4) no default, event of default or other event or condition shall have occurred and be continuing that provides the applicable LNG Buyer the right to cancel or terminate such Qualifying LNG SPA in accordance with the terms thereof;

 

  (B)

a certificate of the Obligor that is party to such agreement certifying that (1) the copy of such agreement provided to the Facility Lenders is a true, correct and complete copy of such document, and (2) such agreement is in full force and effect and no term or condition of such agreement has been amended from the form thereof delivered to the Facility Lenders prior to the Upsize Closing Date (other than amendments in accordance with the Finance Documents and provided to the Intercreditor Agent); and

 

-31-

Plaquemines – Amended & Restated Common Terms Agreement


  (C)

with respect to any Qualifying LNG SPA executed subsequent to the Initial Closing Date, a Direct Agreement, substantially in the form attached as Schedule G (Forms of Direct Agreement) of the Common Security and Account Agreement (or otherwise reasonably acceptable to the Facility Lenders);

 

  (ii)

with respect to each Material Project Agreement (including the Excess Capacity LNG SPAs and other than any Subsequent Material Project Agreement or any Replacement Material Contract and other than as provided in sub-clause (i) above with respect to the LNG SPAs):

 

  (A)

a copy of such agreement (other than any Restricted Document which shall be delivered in accordance with the requirements of Section 12.6(c) (Confidentiality) of the Common Security and Account Agreement and Section 23.7 (Confidentiality) below), which shall have been duly authorized, executed and delivered by the parties thereto, as to which no force majeure event (as defined in each such Material Project Agreement) has occurred and is continuing except as set forth on Schedule H (Material Project Agreements and Certain Other Contracts);

 

  (B)

a certificate of the Obligor that is party to such agreement certifying that (1) the copy of such agreement provided to the Facility Lenders is a true, correct and complete copy of such document, and (2) such agreement is in full force and effect and no term or condition of such agreement has been amended from the last form thereof delivered to the Facility Lenders prior to the Upsize Closing Date (other than amendments in accordance with the Finance Documents and provided to the Intercreditor Agent); and

 

  (C)

a Direct Agreement, either substantially in the form attached as Schedule G (Forms of Direct Agreement) of the Common Security and Account Agreement (or otherwise reasonably acceptable to the Collateral Agent), with each counterparty to such agreement, to the extent such Direct Agreement is required to be delivered by the Upsize Closing Date pursuant to Section 3.4 (Direct Agreements) of the Common Security and Account Agreement;

 

-32-

Plaquemines – Amended & Restated Common Terms Agreement


  (iii)

with respect to each Material Project Agreement (other than any Subsequent Material Project Agreement or any Replacement Material Contract), a copy of all performance security, letters of credit and guarantees (A) required to be delivered under each Material Project Agreement by the Material Project Counterparties as of the Upsize Closing Date and (B) delivered by one or more parent companies of the Pledgor to Material Project Counterparties (all of which, for the avoidance of doubt, will be replaced by Letters of Credit following the Upsize Closing) and a certificate of each Obligor that copies of all such performance security, letters of credit and guarantees required to be delivered pursuant to this clause (iii) have been provided to the Facility Lenders; and

 

  (iv)

all Material Project Agreements (or any amendments thereto) that were made available for viewing to the Facility Lenders after the date of the Upsize Commitment Letter shall be in form and substance satisfactory to the Facility Lenders.

 

  (c)

Material Project Agreement Default. As of the Upsize Closing Date, no material default or event of default of any Obligor, and to the Knowledge of each Obligor, no material default or event of default of any counterparty exists under any Material Project Agreement;

 

  (d)

FERC Order. The FERC Order:

 

  (i)

has been obtained by the Borrower with respect to the LNG Facility and by the Guarantor with respect to the Gator Express Pipeline;

 

  (ii)

is in full force and effect;

 

  (iii)

is final and non-appealable; and

 

  (iv)

is free from conditions and requirements:

 

  (A)

the compliance with which could reasonably be expected to have a Material Adverse Effect; or

 

  (B)

that the applicable Obligor does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development except to the extent that failure to satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect;

 

  (e)

Export Authorizations. Each of the FTA Authorization and the Non-FTA Authorization:

 

  (i)

has been obtained by the Borrower;

 

-33-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

is in full force and effect;

 

  (iii)

is free from conditions or requirements:

 

  (A)

the compliance with which could reasonably be expected to have a Material Adverse Effect; or

 

  (B)

that the Borrower does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development except to the extent that failure to so satisfy such condition could not reasonably be expected to have a Material Adverse Effect;

 

  (f)

Opinions from Counsel. Receipt by the Intercreditor Agent and the Credit Facility Secured Parties of the legal opinions and reliance letters set forth in Schedule C - 2 (Table of Requirements for Legal Opinions – Conditions to Upsize Closing) and in accordance with the requirements therein, with such changes thereto as may be in form and substance reasonably satisfactory to the Intercreditor Agent;

 

  (g)

Project Development. Receipt by the Intercreditor Agent of true, complete and correct copies of:

 

  (i)

a certificate of the Obligors attaching the updated Construction Budget and Schedule with respect to the Development, substantially in the form attached as Schedule D - 1 (Construction Budget and Schedule – Construction Budget) and Schedule D - 2 (Construction Budget and Schedule – Construction Schedule) hereto, which shall include a list or schedule of the amount of Project Costs paid by the Obligors with respect to the Phase 2 LNG Facility prior to the Upsize Closing Date, and certifying that: (A) such budget and schedule is the best reasonable estimate of the information set forth therein as of the date of such certificate; and (B) such budget and schedule is based on assumptions made in good faith and believed reasonable at the time made in light of the legal and factual circumstances then applicable to the Development and is consistent with the requirements of the Transaction Documents;

 

  (ii)

a certificate of the Obligors attaching the updated Base Case Forecast, which demonstrates compliance with the Base Case Sizing Criteria, and certifying that: (A) the projections in the Base Case Forecast were made in good faith; and (B) the assumptions on the basis of which such projections were made were believed by the Borrower (when made and delivered) to be reasonable and consistent with the Construction Budget and Schedule and the Transaction Documents;

 

-34-

Plaquemines – Amended & Restated Common Terms Agreement


  (iii)

an updated final report of the Independent Engineer (including certifications and discussions therein relating to the adequacy of the contingency relating to the Project to satisfy potential cost overruns with respect to the Development), together with a reliance letter from the Independent Engineer in form and substance reasonably satisfactory to the Credit Facility Agent;

 

  (iv)

a final report of the CCRA Consultant, together with a reliance letter from the CCRA Consultant in form and substance reasonably satisfactory to the Credit Facility Agent;

 

  (v)

the reports entitled “Plaquemines LNG Project – Updated Final Commercial Due Diligence Report,” dated March 14, 2022 and “Independent Commercial Evaluation Report – Plaquemines Phase 2 LNG Project,” dated February 3, 2023, together with a reliance letter from the Market Consultant in form and substance reasonably satisfactory to the Credit Facility Agent;

 

  (vi)

final reports prepared by the Environmental Consultants, described on Schedule X (Phase I Environmental Assessments) hereto, together with a reliance letter from each Environmental Consultant, each in form and substance reasonably satisfactory to the Credit Facility Agent; and

 

  (vii)

a certificate of the Independent Engineer (A) concurring with the Borrower’s certification in sub-clause (i) above and (B) validating the Obligors’ list or schedule of the amount of Project Costs in relation to the Phase 2 LNG Facility paid by the Borrower prior to the Upsize Closing Date referred to in sub-clause (i) above, which such list shall specify such Project Costs paid (x) from the Excess Equity Proceeds Account and (y) by the Sponsor;

 

  (h)

Financial Statements. Receipt by the Intercreditor Agent of:

 

  (i)

a certified copy of the most recent pro forma balance sheet of each Obligor;

 

  (ii)

copies of the most recent financial statements of the Obligors delivered pursuant to Section 10.1(a)(i) of the Original Common Terms Agreement, together with a certificate executed by an Authorized Officer of each of the Obligors certifying that such financial statements fairly present in all material respects the financial condition and results of operations of the Obligors on the dates and for the periods indicated in accordance with GAAP, subject to the absence of notes and normal year-end audit adjustments; and

 

-35-

Plaquemines – Amended & Restated Common Terms Agreement


  (iii)

to the extent delivered to the Borrower or the Guarantor under any Material Project Agreement, financial statements of the Material Project Counterparties;

 

  (i)

Insurance. Receipt by the Intercreditor Agent of:

 

  (i)

a report from the Insurance Advisor, prepared in accordance with generally accepted consulting practices together with a certificate of the Insurance Advisor confirming that the insurance policies to be provided in compliance with Section 12.28 (Insurance Covenant) conform to the requirements specified in the Finance Documents and are in accordance with Prudent Industry Practices; and

 

  (ii)

a reliance letter from the Insurance Advisor in form and substance reasonably satisfactory to the Credit Facility Agent;

 

  (j)

[Reserved].

 

  (k)

Bank Regulatory Requirements. Receipt by the Intercreditor Agent and each other Finance Party that is a party to this Agreement:

 

  (i)

at least three Business Days prior to the Upsize Closing Date, with respect to each of the Collateral Parties, of a certified electronic copy of each of the documents listed in Schedule E (Know Your Customer Documentation) that are required in order for each Facility Lender to carry out all necessary “know your customer” or similar requirements and such other information as may be reasonably required by such Facility Lender to address such requirement, including those reasonably required to ensure compliance with anti- money laundering procedures (including the USA Patriot Act) in its relevant jurisdiction, in each case to the extent not otherwise delivered to the relevant Finance Party at or prior to the Upsize Closing Date (and provided that any subsequent changes in such documents or updates to information contained therein shall be so delivered in accordance with this clause (k)(i)); and

 

  (ii)

at least three Business Days prior to the Upsize Closing Date, a Beneficial Ownership Certification from the Borrower if it qualifies as a “legal entity customer” under the Beneficial Ownership Regulation;

 

-36-

Plaquemines – Amended & Restated Common Terms Agreement


  (l)

Officer’s Certificates. Receipt by the Intercreditor Agent of a copy of a duly executed certificate of each of the Collateral Parties and, with respect to sub-clauses (i)—(iii) below, of each Affiliated Service Counterparty:

 

  (i)

attaching a copy of the Constitutional Documents of each of the Collateral Parties and each Affiliated Service Counterparty, together with any amendments thereto (and certifying that such Constitutional Documents have not been revoked or amended since the date of the attached Constitutional Documents);

 

  (ii)

attaching copies of resolutions approving the Collateral Parties’ and the Affiliated Service Counterparties’ entry into the Finance Documents and Material Project Agreements, as applicable (and certifying that such resolutions have not been revoked or amended since the date of adoption thereof);

 

  (iii)

attaching incumbency certificates in respect of signatories; and

 

  (iv)

certifying that the conditions in clauses (c) (Material Project Agreement Default) and (m) (Representations and Warranties) of this Section 4.2 (Conditions to Upsize Closing Date) have been met;

 

  (m)

Representations and Warranties. Each of the representations and warranties of the Obligors as set forth under Article 5 (Representations and Warranties of the Obligors) of this Agreement is true and correct in all material respects (except for those qualified by materiality, each of which shall be true and correct in all respects) as to such Obligor on and as of the Upsize Closing Date as if made on and as of the Upsize Closing Date (or if stated to have been made solely as of an earlier date, as of such earlier date);

 

  (n)

LNG SPAs. No actual LNG SPA Prepayment Event or Unmatured LNG SPA Prepayment Event (i) has occurred and is continuing or (ii) could reasonably be expected to occur after giving effect to the Project Phase 2 Development;

 

  (o)

Lien Search; Perfection of Security. Receipt by the Collateral Agent of copies or evidence, as the case may be, of the following actions in connection with the perfection of the Collateral:

 

  (i)

completed requests for information or copies of the UCC search reports and tax lien, judgment and litigation search reports for the State of Delaware and the State of Louisiana, and any other jurisdiction reasonably requested by any of the Facility Agents that name each Obligor or the Pledgor as debtor, together with copies of each UCC financing statement, fixture filing or other filings listed therein, which evidences no Liens on the Collateral, other than Permitted Liens; all dated within 15 Business Days prior to the Upsize Closing Date;

 

-37-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

UCC financing statements, fixture filings or other filings reflecting the Liens granted pursuant to the Common Security and Account Agreement and the other Security Documents that any of the Facility Agents may deem necessary or desirable in order to perfect the first priority Liens (subject only to Permitted Liens) created thereunder; and

 

  (iii)

the Collateral is subject to the perfected first priority Lien (subject only to Permitted Liens) established pursuant to the Security Documents;

 

  (p)

Fees; Expenses. Irrevocable instructions for the payment to each of the Facility Agents for its own account, or for the account of the relevant Facility Lender entitled thereto, of all fees due and payable as of the Upsize Closing Date pursuant to the Finance Documents, and all costs and expenses (including reasonable costs, fees and expenses of legal counsel and Consultants) payable thereunder for which reasonably detailed invoices have been presented to the Borrower at least two Business Days prior to the Upsize Closing Date;

 

  (q)

Authority to Conduct Business. Receipt by the Intercreditor Agent of satisfactory evidence, including certificates of good standing, dated no more than five Business Days prior to the Upsize Closing Date, from the Secretary of the State of Louisiana and the Secretary of State of the State of Delaware, as applicable, of the authority of each Collateral Party and Affiliated Service Counterparty to carry on its business;

 

  (r)

Total Capitalization. The aggregate Term Loan Commitments are not more than 75% of the then-current estimate of Project Costs projected in the Construction Budget and Schedule as of the Upsize Closing Date to be incurred by the Obligors for the Development;

 

  (s)

Lien Waivers. Receipt by the Intercreditor Agent of Lien Waivers as have then been required pursuant to each of the Phase 2 Material Construction Contracts;

 

  (t)

Flood Insurance. Receipt by each of the Facility Lenders of the following flood coverage documents from the Borrower, in each case to be satisfactory to each of the Facility Lenders:

 

-38-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

a Flood Certificate with respect to the Mortgaged Property, which Flood Certificate shall:

 

  (A)

be addressed to the Credit Facility Agent;

 

  (B)

provide for “life of loan” monitoring; and

 

  (C)

otherwise comply with the Flood Program;

 

  (ii)

if the Flood Certificate states that any structure comprising a portion of the anticipated Mortgaged Property will be located in a special flood hazard area (as defined pursuant to applicable flood insurance regulations), the Borrower’s written acknowledgment of receipt of written notification from the Credit Facility Agent and any Facility Lender requesting the same:

 

  (A)

as to the existence of such Mortgaged Property; and

 

  (B)

as to whether the community in which such Mortgaged Property will be located is participating in the Flood Program;

 

  (u)

Notes. Receipt of copies of the notes requested by the Facility Lenders pursuant to their Facility Agreement, as applicable, duly authorized, executed and delivered by the Borrower;

 

  (v)

Litigation; Regulatory Action. There are no actions, suits, proceedings, investigations or similar actions pending or, to the knowledge of each Obligor, threatened (in writing) against such Obligor that have had or could reasonably be expected to have a Material Adverse Effect;

 

  (w)

No Force Majeure. To the knowledge of the Obligors, no event of force majeure (as defined under the applicable Material Project Agreement) has occurred and is continuing under any Material Project Agreement the consequences of which could reasonably be expected to have a Material Adverse Effect;

 

  (x)

Absence of Default. No Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing on such date or could reasonably be expected to result from the consummation of the transactions contemplated by the Transaction Documents;

 

  (y)

Equity Funding Commitments and Minimum Funded Amount.

 

  (i)

At least $1,667,029,445.58 shall have been contributed to the Borrower on the Upsize Closing Date and deposited into the Construction Account (as verified by the Account Bank) concurrently with the consummation of the transactions contemplated by the Transaction Documents; and

 

-39-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

the Senior Debt/Equity Ratio shall be no greater than 75:25 after giving effect to any Equity Funding on the Upsize Closing Date;

 

  (z)

Notice to Proceed. Issuance by the Borrower of the “Notice to Proceed” or “FNTP”, as applicable, under and in accordance with the Phase 2 EPC Contract;

 

  (aa)

Delivery of Material Permits. The Intercreditor Agent has received a copy of each material Permit (including the FERC Order, the FTA Authorization and Non-FTA Authorization);

 

  (bb)

Funds Flow Memorandum. Delivery by the Borrower of the memorandum setting forth the flow of funds on the Upsize Closing Date;

 

  (cc)

Equator Principles. Reasonable satisfaction of customary Lender diligence in respect of Equator Principles matters, and implementation (to the extent required as of the Upsize Closing Date) in all material respects of the “Equator Principles Action Plan” (as described in the Independent Engineer’s final report); and

 

  (dd)

Insurance. Receipt by each Lender of satisfactory documentary evidence of either (a) the payment of insurance premiums on or before the Upsize Closing Date or (b) the concurrent payment on the Upsize Closing Date, in each case, sufficient to ensure that the Borrower’s flood insurance policy is in full force and effect as of the Upsize Closing Date.

 

  4.3

Conditions to Each Term Loan Advance

Except as specified in Section 14.4(b) (Project Phase 2 Completion Date Waterfall – Final Advance of Term Loans), the obligation of each Facility Lender (other than the Working Capital Lenders) to make available any Advance of Term Loans is subject to the satisfaction or waiver of the following (and, in the case of any Advance of Term Loans other than the Initial Advance, no other) common conditions precedent:

 

  (a)

Disbursement Request. Receipt by the applicable Facility Agent of a Disbursement Request substantially in the form set forth in Schedule B-1 (Disbursement Request Form (Term Loans)) (and in such form as required pursuant to each Facility Agreement), which shall:

 

-40-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

be for an amount that does not exceed (A) Project Costs reasonably expected to be due or incurred within the next 45 days succeeding the date of the proposed Advance minus (B) the amount estimated to be on deposit in the Construction Account on the date of such Advance;

 

  (ii)

include a certification from the Borrower (and, in the case of the certifications set forth in sub-clauses (A), (B), (C) and (D) below, to which the Independent Engineer reasonably concurs):

 

  (A)

that the Independent Engineer has received from the Borrower (1) a detailed breakdown of the Project Costs to be funded pursuant to such Advance and (2) copies of or access to each invoice related to Project Costs incurred since the most recent Advance (or in the case of the first Advance after the Initial Closing Date, since Initial Closing) that is for more than $500,000 (excluding any invoices related to Permitted Hedging Instruments, Senior Debt or any Permitted Finance Costs and non-construction transaction costs and expenses) and, to the extent necessary, additional invoices so that the Independent Engineer has received invoices with respect to each prior Advance representing at least 90% of the applicable Project Costs (excluding any invoices related to Permitted Hedging Instruments, Senior Debt or any Permitted Finance Costs and non-construction transaction costs and expenses) incurred since the most recent Advance;

 

  (B)

that the amount of the Advance being requested (1) is supported by such information provided by the Obligors to the Independent Engineer and certified by the Borrower as true, correct and complete with respect to the matter under review or (2) with respect to any evidence that constitutes estimated information, is based on reasonable good faith projections reasonably satisfactory to the Independent Engineer; provided that the Independent Engineer will not be required to evaluate the reasonableness of the projections with respect to funds used or funds related to payments under Permitted Hedging Instruments, Senior Debt, any Permitted Finance Costs and non-construction transaction costs or expenses;

 

  (C)

(1) that the construction of the Project Facilities is proceeding substantially in accordance with the construction schedule set out in the Construction Budget and Schedule or, if not so proceeding, any delays shall, prior to the Project Phase 1 Completion Date, not be reasonably expected to

 

-41-

Plaquemines – Amended & Restated Common Terms Agreement


  cause the Project Phase 1 Completion Date to otherwise not be achieved by the Phase 1 LNG Facility Date Certain or not be reasonably expected to cause the Project Phase 2 Completion Date to otherwise not be achieved by the Phase 2 LNG Facility Date Certain and, after the Project Phase 1 Completion Date and prior to the Project Phase 2 Completion Date, not be reasonably expected to cause the Project Phase 2 Completion Date to otherwise not be achieved by the Phase 2 LNG Facility Date Certain, (2) as to the current utilization of previous Advances and (3) that the Facility Debt Commitments, and funds on deposit in the Construction Account, Contingency Reserve Account and the Permitted Finance Costs Reserve Account (including any Equity Funding remaining on deposit in the Construction Account) are sufficient, prior to the Project Phase 1 Completion Date, to achieve the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain and, after the Project Phase 1 Completion Date and prior to the Project Phase 2 Completion Date, to achieve the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain;

 

  (D)

that the Independent Engineer has received evidence that the full amount of the proceeds of the last preceding Advance has been either (1) paid in accordance with the Finance Documents or (2) retained in the Construction Account;

 

  (E)

that construction reports that are then due pursuant to Section 10.4 (Construction Reports) have been provided to the Intercreditor Agent;

 

  (F)

that the Borrower reasonably believes, prior to the Project Phase 1 Completion Date, that the Project Phase 1 Completion Date shall occur on or prior to the Phase 1 LNG Facility Date Certain and the Project Phase 2 Completion Date shall occur on or prior to the Phase 2 LNG Facility Date Certain and, after the Project Phase 1 Completion Date and prior to the Project Phase 2 Completion Date, that the Project Phase 2 Completion Date shall occur on or prior to the Phase 2 LNG Facility Date Certain;

 

  (G)

that each of the conditions in clauses (b) (Representations and Warranties), (c) (Absence of Default), (d) (Permits), (e) (Collateral), (i) (Senior Debt/Equity Ratio) and (j) (Export Authorizations) below have been met;

 

-42-

Plaquemines – Amended & Restated Common Terms Agreement


  (H)

none of the Construction Contractors has sought a Change Order to which such Construction Contractor is entitled for any EPC Change in Law as contemplated under Section 12 (Changes in the Work) of the Phase 1 EPC Contract, Section 12 (Changes in the Work) of the Phase 2 EPC Contract or the corresponding provision of the Material Construction Contract that would, taking into account the increase in the contract price thereunder, cause the condition set forth in sub-clause (C) above not to be satisfied; and

 

  (I)

as to compliance with the Senior Debt/Equity Ratio specified in clause (i) of this Section 4.3 (Conditions to Each Term Loan Advance);

 

  (iii)

include either (A) a list of all Change Orders for more than $20 million not theretofore submitted to the Intercreditor Agent, together with a statement by the Borrower that copies of the same have been submitted to the Independent Engineer prior to the date of the applicable Disbursement Request or (B) a Borrower statement that all Change Orders for more than $20 million have previously been submitted to the Intercreditor Agent and the Independent Engineer;

 

  (b)

Representations and Warranties. Each of the Repeated Representations made by such Obligor is true and correct in all material respects, except for those representations and warranties that are qualified by materiality, which shall be true and correct in all respects, as to such Obligor on and as of the date of such Advance as if made on and as of such date (or, if stated to have been made solely as of an earlier date, as of such earlier date);

 

  (c)

Absence of Default. No Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing on such date or could reasonably be expected to result from the consummation of the transactions contemplated by the Transaction Documents;

 

  (d)

Permits. The Intercreditor Agent shall have received a copy of each material Permit to the extent required by Section 10.4(b)(x) (Construction Reports).

 

  (e)

Collateral. The Collateral is subject to the perfected first priority Lien (subject only to Permitted Liens) in accordance with the requirements of, and established pursuant to, the Security Documents.

 

-43-

Plaquemines – Amended & Restated Common Terms Agreement


  (f)

Real Property. Receipt by the Collateral Agent of a Disbursement Endorsement;

 

  (g)

Lien Waivers. Receipt by the Intercreditor Agent of Lien Waivers as have then been required pursuant to each of the Material Construction Contracts and Site Works Contracts;

 

  (h)

Fees; Expenses. Receipt by each of the Facility Agents for its own account, or for the account of the relevant Facility Lender entitled thereto, of, or issuance of irrevocable instructions to pay from the proceeds of the Advance, all fees due and payable on and as of the date of the Advance pursuant to the Finance Documents, and all costs and expenses (including reasonable costs, fees and expenses of legal counsel and Consultants) payable thereunder for which reasonably detailed invoices have been presented to the Borrower at least three Business Days prior to the Advance;

 

  (i)

Senior Debt/Equity Ratio. The Senior Debt/Equity Ratio shall be no greater than 75:25, as confirmed by the Borrower (or, if the Senior Debt/Equity Ratio is greater than 75:25, a corresponding amount of Equity Funding shall be made concurrently with the applicable Advance to cause the Senior Debt/Equity Ratio to be no greater than 75:25); and

 

  (j)

Export Authorizations. No Impairment of any Required Export Authorization with respect to any Required LNG SPA has occurred and is continuing that could reasonably be expected to result in a Material Adverse Effect. For the avoidance of doubt, if such an Impairment ceases to be continuing, whether as a result of an Export Authorization Remediation or otherwise, this condition will be deemed fulfilled.

 

  4.4

Conditions to Each Advance under the Working Capital Facility

The obligation of each Working Capital Lender to make available any Advance of Upsized Senior Debt is subject to the satisfaction or waiver of the following (and no other) common conditions precedent:

 

  (a)

Disbursement Request. If such disbursement request is a request for Working Capital Loans, receipt by the Credit Facility Agent of a Disbursement Request substantially in the form set forth in Schedule B-2 (Disbursement Request Form (Working Capital Loans));

 

  (b)

Issuance Request. If such disbursement request is a request for Letters of Credit, receipt by the Credit Facility Agent of an Issuance Request substantially in the form set forth in Schedule B-3 (Issuance Request Form (Letters of Credit));

 

-44-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

Absence of Default. No Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing on such date or could reasonably be expected to result from the consummation of the transactions contemplated by the Transaction Documents; and

 

  (d)

Representations and Warranties. Each of the Repeated Representations made by each Obligor is true and correct in all material respects, except for those representations and warranties that are qualified by materiality, which shall be true and correct in all respects, as to such Obligor on and as of the date of such Advance as if made on and as of such date (or, if stated to have been made solely as of an earlier date, as of such earlier date).

 

  4.5

Satisfaction of Conditions

 

  (a)

In relation to the Initial Closing and the Initial Advance:

 

  (i)

each of the conditions precedent set forth in Section 4.1 (Conditions to Initial Closing Date and Initial Advance) and Section 4.3 (Conditions to Each Term Loan Advance) was satisfied or waived on the Initial Closing Date, (x) the Borrower delivered to the Intercreditor Agent a certificate to such effect (such certificate, the “Initial Closing Conditions Certificate”) and (y) the Intercreditor Agent delivered the Initial Closing Conditions Certificate to the Credit Facility Agent and, the Intercreditor Agent countersigned the Initial Closing Conditions Certificate and delivered the same to the Credit Facility Agent, solely for the purpose of acknowledging receipt of the Initial Closing Conditions Certificate and confirming such waivers (if any), and delivered such countersigned certificate to the Borrower (such countersigned Initial Closing Conditions Certificate referred to as the “Initial Closing Notice”); and

 

  (ii)

the Disbursement Request with respect to the Initial Advance was delivered by the Borrower following the delivery of the Initial Closing Notice in accordance with the applicable requirements set forth in the Credit Facility Agreement.

 

  (b)

In relation to the Upsize Closing, if each of the conditions precedent set forth in Section 4.2 (Conditions to Upsize Closing Date) has been satisfied or waived, (x) the Borrower shall deliver to the Intercreditor Agent a certificate to such effect (such certificate, the “Upsize Closing Conditions Certificate”) and (y) the Intercreditor Agent shall deliver the Upsize Closing Conditions Certificate to the Credit Facility Agent and unless a separate instrument effecting any such waiver has been signed by each of the relevant Parties, the Intercreditor Agent shall countersign the Upsize Closing Conditions Certificate and deliver the same to the Credit Facility

 

-45-

Plaquemines – Amended & Restated Common Terms Agreement


  Agent, solely for the purpose of acknowledging receipt of the Upsize Closing Conditions Certificate and confirming such waivers (if any), and deliver such countersigned certificate to the Borrower or otherwise provide the Borrower with a written confirmation of its receipt of the Borrower’s Upsize Closing Conditions Certificate (such countersigned Upsize Closing Conditions Certificate, or such Upsize Closing Conditions Certificate together with the Intercreditor Agent’s written confirmation of receipt thereof, is collectively referred to as the “Upsize Closing Notice”). The occurrence of the Upsize Closing and the obligation of each Term Lender (as defined in the Credit Facility Agreement) to make the initial Advance following the Upsize Closing Date is subject to the Intercreditor Agent’s delivery of the Upsize Closing Notice to the Borrower prior to or concurrently with the Upsize Closing.

 

  (c)

In relation to each Advance made under any Additional Senior Debt such Advance shall be subject to satisfaction or waiver of such conditions precedent as may be set forth in the Facility Agreement for such Additional Senior Debt.

 

  (d)

In relation to each Advance under a Facility Agreement, the Intercreditor Agent may waive one or more conditions precedent set out in this Article 4 (Conditions Precedent) or any additional conditions to disbursements under the applicable Facility Agreement upon receiving instructions regarding any such waiver from the Facility Agent under the Facility Agreement related to such Advance and the Intercreditor Agent shall promptly notify the Borrower of such waiver.

 

  (e)

The conditions precedent in this Article 4 (Conditions Precedent) and under any Facility Agreement shall be interpreted to permit a single certificate from a Party certifying as to matters required by multiple sections and subsections of this Article 4 (Conditions Precedent).

 

5.

REPRESENTATIONS AND WARRANTIES OF THE OBLIGORS

 

  5.1

Initial Representations and Warranties of the Obligors

Each Obligor makes the following, and no other, common representations and warranties to each Facility Lender. Each such representation and warranty is made at the Upsize Closing Date only:

 

  (a)

Conduct of Business

In respect of each Obligor, it is not engaged in any business other than the Development as contemplated by its Constitutional Documents and the Transaction Documents then in effect.

 

-46-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

Material Permits

 

  (i)

All material Permits (other than the FERC Order and the Export Authorizations) necessary for the Development are set forth in Schedule F (Material Permits) hereto, and:

 

  (A)

as to those identified as such in the relevant schedule, have been duly obtained, were validly issued, are in full force and effect, and are not the subject of any pending appeal (or if subject to any appeal, such appeal does not have a reasonable probability of success and the applicable permit remains effective during such appeal) and all applicable fixed time periods for appeal set forth in the Government Rules pursuant to which such Permits were issued have expired or are Permits that do not have limits on appeal periods; or

 

  (B)

as to those identified as such in the relevant schedule, are expected by the Obligors to be obtained in the ordinary course by the time they are necessary for the Development; and

 

  (C)

in the case of the Permits described in sub-clause (A) above, are, or, in the case of the Permits described in sub-clause (B) above, are reasonably expected to be, free from conditions or requirements:

 

  (1)

the compliance with which could reasonably be expected to have a Material Adverse Effect; or

 

  (2)

which the Obligors do not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development for which such Permit is necessary, except to the extent that a failure to so satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect.

 

  (ii)

In respect of each Obligor, to its Knowledge, there is no action, suit or proceeding pending with respect to any material Permit set forth in Schedule F (Material Permits) attached hereto (not including the FERC Order or any Export Authorization) that could reasonably be expected to result in a Material Adverse Effect or if subject to any appeal, such appeal does not have a reasonable probability of success and the applicable permit remains effective during such appeal.

 

-47-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

Compliance with Laws

Except to the extent already contemplated under this Article 5 (Representations and Warranties of the Obligors) hereof, each Obligor is in material compliance with all material applicable Government Rules.

 

  (d)

No Employees

None of the Obligors has any current or former employees.

 

  (e)

Labor Matters

In respect of each Obligor, no strikes, lockouts or slowdowns in connection with it or the Project Facilities exist or, to its Knowledge, are threatened that could reasonably be expected to have a Material Adverse Effect.

 

  (f)

Legal Name and Place of Business

 

  (i)

The full and correct legal name, type of organization and jurisdiction of organization of each of the Obligors is as follows:

 

  (A)

Venture Global Plaquemines LNG, LLC, a limited liability company organized under the laws of the State of Delaware; and

 

  (B)

Venture Global Gator Express, LLC, a limited liability company organized under the laws of the State of Delaware.

 

  (ii)

Except as set forth on Schedule 5.1(f)(ii) (Prior Locations), no Obligor has ever changed its name or location (as defined in Section 9-307 of the UCC); and

 

  (iii)

On the Upsize Closing Date, the chief executive offices of the Obligors are located at 1001 19th Street North, Suite 1500, Arlington, VA 22209.

 

  (g)

Sanctions, Anti-Corruption Laws and USA Patriot Act

The use of the proceeds of the Loans does not violate, and will not cause a violation by any person of, any Applicable Anti-Corruption Laws, Anti- Terrorism and Money Laundering Laws, or Sanctions, and none of the Obligors, the Sponsor or any of their respective Affiliates, nor, to the Knowledge of the Obligors, any of their respective directors, officers or employees, is:

 

-48-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

the target of Sanctions administered by the United States, including by OFAC and by the US Department of State, the European Union, any EU member state, or His Majesty’s Treasury of the United Kingdom;

 

  (ii)

a Person listed in any Sanctions-related list of sanctioned Persons maintained by the United States, including by OFAC and the U.S. Department of State, by the United Nations Security Council, the European Union, any EU member state, or the His Majesty’s Treasury of the United Kingdom;

 

  (iii)

a Person located, organized or resident in a country, territory, or region that is, or whose government is, the target of Sanctions under OFAC or by the US Department of State, the European Union, any EU member state, or His Majesty’s Treasury or the United Kingdom (as of the date of this Agreement, Cuba, Iran, North Korea, Syria, the Crimea region of Ukraine, the so-called Donetsk People’s Republic and the so-called Luhansk People’s Republic, and the non- government controlled areas of Ukraine in the oblasts of Zaporizhzhia and Kherson);

 

  (iv)

a Person owned or controlled by a Person or Persons, country, territory, or region in (i) through (iii) (each such person in (i) through (iv), a “Sanctioned Person”); or

 

  (v)

the subject of any action or investigation by any Governmental Authority with respect to any actual or alleged violation of any Applicable Anti-Corruption Laws, Anti-Terrorism and Money Laundering Laws, or Sanctions.

The Obligors and the Sponsor, and, to the Knowledge of the Obligors, their respective Affiliates, directors, officers and employees, are in material compliance with Applicable Anti-Corruption Laws, Anti-Terrorism and Money Laundering Laws, and Sanctions.

The Obligors and the Sponsor and, to the Knowledge of the Obligors, their respective Affiliates have instituted and maintain policies and procedures reasonably designed to promote compliance with Applicable Anti- Corruption Laws, Anti-Terrorism and Money Laundering Laws, and Sanctions.

 

  (h)

Financial Condition

In respect of each Obligor, there has been no change in its financial condition, operations or business since the date of the financial statements referred to in Section 4.2(h) (Conditions to Upsize Closing Date – Financial Statements) that could reasonably be expected to have a Material Adverse Effect.

 

-49-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

Information; Projections

In respect of each Obligor, except as otherwise disclosed by it in writing, no information furnished in writing to the Senior Creditors by or on behalf of it in connection with the transactions contemplated by the Transaction Documents or delivered to the Collateral Agent, any Consultant or a Facility Agent in connection therewith (or their counsel), when taken as a whole, contains, as of the date of such information, any untrue statement of a material fact pertaining to it or the Development or omits to state a material fact pertaining to it or the Development necessary to make the statements contained herein or therein not misleading in any material respect (provided that no representation or warranty is made with respect to any forecast, estimate, forward-looking information, information of a general economic or general industry nature or pro forma calculation made in the Construction Budget and Schedule, this Agreement or Base Case Forecast, including with respect to the start of operations of the Project Facilities, the Project Phase 1 Completion Date, the Project Phase 2 Completion Date, final capital costs or operating costs of the Development, oil prices, Gas prices, LNG prices, electricity prices, Gas reserves, rates of production, Gas market supplies, LNG market demand, exchange rates or interest rates, rates of taxation, rates of inflation, transportation volumes or any other forecasts, projections, assumptions, estimates or pro forma calculations, except that they are based on assumptions made in good faith and believed reasonable at the time made in light of the legal and factual circumstances then applicable to the Development, and it makes no representation as to the actual attainability of any projections set forth in the Base Case Forecast or Construction Budget and Schedule, or any such other items listed in this proviso). Without limiting the generality of the foregoing, no representation or warranty shall be made by any Obligor as to any information or material provided by a Consultant (except to the extent such information or material originated with such Obligor).

 

  (j)

Environmental and Social

Except as set forth in Schedule G (Disclosure Schedule) hereto:

 

  (i)

Except as could not reasonably be expected to result in a Material Adverse Effect, each Obligor and the Project Facilities are, and have been, in compliance with all applicable Environmental Laws;

 

-50-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

there are no past or present facts, circumstances, conditions, events or occurrences, including Releases of Hazardous Materials by the Obligors or with respect to the Project Facilities or any Real Estate on which any Project Facilities are located, that could reasonably be expected to give rise to any Environmental Claims that could reasonably be expected to have a Material Adverse Effect or cause the Project Facilities to be subject to any restrictions on ownership, occupancy, use or transferability under any Environmental Laws that could reasonably be expected to have a Material Adverse Effect (excluding restrictions on the transferability of Permits upon the transfer of ownership of assets subject to such Permit);

 

  (iii)

Hazardous Materials have not at any time been Released at, on, under or from the Project Facilities, or any Real Estate on which they are situated, by an Obligor or, to the Knowledge of such Obligor, other Persons, other than in material compliance at all times with all applicable Environmental Laws or in such manner as otherwise could not reasonably be expected to result in a Material Adverse Effect;

 

  (iv)

there have been no material environmental investigations, studies, audits, reviews or other analyses relating to environmental site conditions that individually or in the aggregate could reasonably be expected to have a Material Adverse Effect and that have been conducted by, or that are in the possession or control of, the Obligors in relation to the Project Facilities, or any Real Estate on which they are situated, that have not been provided to the Collateral Agent; and

 

  (v)

the Obligors have not received any letter or request for information under Section 104 of CERCLA, or comparable state laws, and to the Knowledge of the Obligors, none of the operations of the Obligors is the subject of any investigation by a Governmental Authority evaluating whether any remedial action is needed to respond to a Release or threatened Release of any Hazardous Materials relating to the Project Facilities, or any Real Estate on which they are situated, or at any other location, including any location to which the Obligors have transported, or arranged for the transportation of, any Hazardous Materials with respect to the Development, which, in each case above, could reasonably be expected to have a Material Adverse Effect.

 

-51-

Plaquemines – Amended & Restated Common Terms Agreement


  (k)

Taxes

In respect of each Obligor, it (or, for the purposes of this clause (k) as it relates to U.S. federal income taxes, if it is a disregarded entity for U.S. federal income tax purposes, its first regarded owner for U.S. federal income tax purposes) has timely filed or caused to be filed all income tax returns that are required to be filed by or in respect of such Obligor and all other material tax returns that are required to be filed, and has paid (i) all Taxes shown to be due and payable on such returns or on any material assessments made against or in respect of such Obligor or any of its property and (ii) all other material Taxes imposed on or in respect of such Obligor or its property by any Governmental Authority (other than Taxes that are being contested in good faith by appropriate proceedings diligently conducted and for which adequate reserves are being maintained in accordance with GAAP), and no tax Liens (other than Permitted Liens) have been filed and no claims are being asserted with respect to any such Taxes (other than claims which are being contested in good faith).

 

  (l)

Regulatory Matters

 

  (i)

None of the Obligors is subject to regulation:

 

  (A)

under Section 3 of the Natural Gas Act;

 

  (B)

as a “natural-gas company” as such term is defined in the Natural Gas Act;

 

  (C)

under PUHCA; or

 

  (D)

under the Louisiana Government Rules as a “public utility” or a “gas utility”;

provided that the Borrower is subject to the provisions of Section 3 of the Natural Gas Act (1) for the siting, construction, expansion, and operation of the LNG Facility and (2) with respect to the export of LNG from the LNG Facility; and provided, further, that the Guarantor is subject to Section 7 of the Natural Gas Act with respect to the construction and operation of the Gator Express Pipeline, and each of the Obligors will become subject to provisions of the Natural Gas Act as a “natural-gas company” at such time as the Obligors, as applicable, engage in the transportation of “natural gas” (as such term is defined in the Natural Gas Act) in interstate commerce or the sale in interstate commerce of natural gas for resale; however, the Borrower will be subject to regulation as a “natural-gas company” under the Natural Gas Act only to the extent of natural gas sales pursuant to Part 284, Subpart L of FERC’s regulations.

 

-52-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

None of the Collateral Agent nor the Senior Creditors, solely by virtue of the execution and delivery of the Finance Documents, the consummation of the transactions contemplated thereby, or the performance of obligations thereunder, shall be or become subject to the provisions of:

 

  (A)

Section 3 of the Natural Gas Act;

 

  (B)

the Natural Gas Act as a “natural-gas company” as such term is defined in such Act;

 

  (C)

PUHCA; or

 

  (D)

the Louisiana Government Rules as a “public utility” or a “gas utility”.

 

  (m)

Transactions with Affiliates

In respect of each Obligor, it has not entered into any material agreement (other than the Material Project Agreements and any other agreements permitted by Section 12.21 (Transactions with Affiliates)) with the Sponsor or any of its Affiliates on terms and conditions which, in the aggregate, are less favorable to it than those that would be applicable in a comparable agreement with independent parties acting at arm’s length (or, if there is no comparable arm’s-length transaction, then on terms reasonably determined by such Obligor (acting through its board of managers, if applicable) to be fair and reasonable).

 

  (n)

Solvency

In respect of each Obligor, it is and, upon the incurrence of any Senior Debt Obligations on the Upsize Closing Date and after giving effect to the transactions and the incurrence of Indebtedness in connection therewith, shall be Solvent.

 

  (o)

Ranking of Senior Debt Obligations

Subject to Section 3.7 (Pro Rata Payment), the Senior Debt Obligations of each Obligor in respect of each Secured Party that is party to the Common Terms Agreement shall rank:

 

  (i)

pari passu in right of payment and otherwise with its Senior Debt Obligations to each other Secured Party under the Finance Documents; and

 

  (ii)

pari passu or senior in right of payment to all other Indebtedness of the Borrower whether now existing or hereafter outstanding.

 

-53-

Plaquemines – Amended & Restated Common Terms Agreement


  (p)

Operating Responsibilities

The administrative and operational responsibilities delegated to the Manager, the Operator and the Pipeline Operator, as applicable, pursuant to the Administrative Services Agreements and the O&M Agreements, collectively, constitute all the administrative and operational responsibilities necessary to comply with the obligations of the Obligors pursuant to the Transaction Documents.

 

  (q)

Material Project Agreements

 

  (i)

A list of each Material Project Agreement existing on the Upsize Closing Date, is attached as Schedule H (Material Project Agreements and Certain Other Contracts) hereto. The Schedule contains details of all amendments, amendments and restatements, supplements, waivers and interpretations modifying or clarifying any of the above. True, correct and complete copies of each of the aforementioned contracts have been delivered to the Intercreditor Agent and certified by the Borrower;

 

  (ii)

To the Knowledge of each Obligor, all Material Project Agreements are in full force and effect;

 

  (iii)

As of the Upsize Closing Date, no material default or event of default of any Obligor and, to the Knowledge of each Obligor, no material default or event of default of any counterparty exists under any Material Project Agreement;

 

  (iv)

To the Knowledge of each Obligor, as of the Upsize Closing Date, the representations and warranties of the Material Project Counterparties under the Material Project Agreements are true and accurate in all material respects;

 

  (v)

As of the Upsize Closing Date, (A) except as set forth on Schedule H (Material Project Agreements and Certain Other Contracts), no event of force majeure (as defined under the applicable Material Project Agreement) in respect of which a Material Project Counterparty has sought or would reasonably be expected to seek relief from performance under a Material Project Agreement has occurred and is continuing under any Material Project Agreement or (B) no other circumstance exists that would entitle a Material Project Counterparty to terminate a Material Project Agreement or suspend its performance thereunder has occurred and is continuing; and

 

-54-

Plaquemines – Amended & Restated Common Terms Agreement


  (vi)

Except as set forth on Schedule H (Material Project Agreements and Certain Other Contracts) hereto, none of the Material Project Agreements has been terminated or otherwise amended, modified, supplemented, transferred, impaired or, to the applicable Obligor’s Knowledge, assigned.

 

  (r)

Equator Principles

As of the Upsize Closing Date, the Obligors are in compliance in all material respects with the Equator Principles.

 

  (s)

Litigation

Except as set forth on Schedule G (Disclosure Schedule) hereto, there are no actions, suits, proceedings, investigations or similar actions pending or, to the knowledge of the Obligors, threatened in writing against the Borrower or the Guarantor that would reasonably be expected to result in a Material Adverse Effect.

 

  (t)

Flood Insurance

The Borrower has complied with the covenant in Section 12.28(c) (Insurance Covenant) and otherwise obtained flood insurance for each portion of the Mortgaged Property located in a special flood hazard area (as defined pursuant to applicable flood insurance regulations) and such insurance is in full force and effect.

 

  (u)

Liabilities

Except as set forth in Schedule G (Disclosure Schedule) hereto, other than liabilities incurred in connection with the consummation of the transactions contemplated by the Transaction Documents, there are no material liabilities of any Obligor of any kind whatsoever, whether accrued, contingent, absolute, determined, determinable or otherwise that would be required to be reflected on a balance sheet of such Obligor prepared in accordance with GAAP other than those liabilities arising in the ordinary course of business and permitted under the Finance Documents.

 

  (v)

Beneficial Ownership Certification

The information included in the Beneficial Ownership Certification is true and correct in all respects.

 

-55-

Plaquemines – Amended & Restated Common Terms Agreement


  (w)

No Event of Loss or Event of Taking

As of the Upsize Closing Date, no material Event of Loss or material Event of Taking has occurred or is, to the Borrower’s Knowledge, threatened or pending.

 

  (x)

Due Authorization

The execution, delivery and performance of the Finance Documents have been duly authorized by all necessary action on the part of each Obligor that is a party thereto.

 

  (y)

No Indebtedness

In respect of each Obligor, it has no Indebtedness other than Indebtedness incurred in accordance with Section 12.14 (Limitation on Indebtedness).

 

  (z)

No Subordinated Debt

As of the Upsize Closing Date, neither Obligor has incurred Subordinated Debt since the Initial Closing Date and no Subordinated Debt is outstanding.

 

  5.2

Repeated Representations and Warranties of the Obligors

Each Obligor makes the following representations and warranties to each Facility Lender. Unless otherwise indicated below, each such representation and warranty is made at the Upsize Closing Date, on the date of each Advance, on the Project Phase 1 Completion Date and on the Project Phase 2 Completion Date:

 

  (a)

Organization

Each of the Obligors is a limited liability company duly organized validly existing and in good standing under the laws of the State of Delaware.

 

  (b)

Financial Statements

The financial statements of the Obligors most recently furnished to the Intercreditor Agent (whether pursuant to Section 4.2(h) (Conditions to Upsize Closing Date – Financial Statements) or Section 10.1(a) (Accounting, Financial and Other Information)) present fairly in all material respects its financial condition as at the date thereof in accordance with GAAP (subject to normal year-end adjustments and except to the extent any notes to the financial statements would not be required thereunder) consistently applied.

 

-56-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

Power and Authority and Qualification

Each Obligor:

 

  (i)

has the power and authority to execute, deliver, perform and incur obligations under the Transaction Documents then in effect to which it is a party;

 

  (ii)

has the power and authority to make the assignment and grant the Lien and Security Interest granted in the Collateral pursuant to the Finance Documents;

 

  (iii)

has the power and authority for the execution, delivery and performance of each of the Transaction Documents to which it is a party, each of the Transaction Documents has been duly authorized by it, and (assuming the due execution and delivery by the counterparties to the Obligors thereto) each of the Transaction Documents to which it is a party is in full force and effect and constitutes a legal, valid and binding obligation of it, enforceable against it in accordance with its terms, except as limited by general principles of equity and bankruptcy, insolvency and similar laws; and

 

  (iv)

is qualified to do business and in good standing in every jurisdiction where its assets are located and wherever necessary to carry out its business and operations, except in jurisdictions where the failure to be so qualified or in good standing has not had, and could not be reasonably expected to have, a Material Adverse Effect.

 

  (d)

No Conflicts

 

  (i)

In respect of each of the Obligors, its Constitutional Documents do not conflict with or prevent execution or delivery or performance by it of the Transaction Documents then in effect to which it is a party;

 

  (ii)

neither (x) any material law applicable to it, or agreement to which it is a party, nor (y) any order, judgment or decree to which it or any of its assets are subject conflict in any material respect with, or prevent execution or delivery or performance by it of, the Transaction Documents then in effect to which it is a party or conflict in any material respect with its Constitutional Documents;

 

  (iii)

in respect of each of the Obligors, the Material Project Agreements then in effect to which it is a party do not conflict with or prevent execution or delivery or performance by it of the Finance Documents; and

 

-57-

Plaquemines – Amended & Restated Common Terms Agreement


  (iv)

the execution or delivery or performance by it of the Transaction Documents does not result in the creation or imposition of any Lien upon or with respect to any of its property or its assets now owned or hereafter acquired, other than Liens created under the Security Documents and other Permitted Liens.

 

  (e)

Regulatory Matters

 

  (i)

the FERC Order: (a) has been obtained by the Borrower with respect to the LNG Facility and by the Guarantor with respect to the Gator Express Pipeline, (b) is in full force and effect, and (c) is final and non-appealable;

 

  (ii)

the Obligors are in material compliance with the FERC Order, and the FERC Order is free from conditions and requirements: (a) the compliance with which could reasonably be expected to have a Material Adverse Effect, or (b) that the applicable Obligor does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development except to the extent that failure to satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect;

 

  (iii)

each of the FTA Authorization and the Non-FTA Authorization: (a) has been obtained by the Borrower, (b) is in full force and effect, and (c) is final and non-appealable; and

 

  (iv)

the Borrower is in material compliance with each of the FTA Authorization and the Non-FTA Authorization, and each of the FTA Authorization and the Non-FTA Authorization is free from conditions and requirements: (a) the compliance with which could reasonably be expected to have a Material Adverse Effect, or (b) that the Borrower does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development except to the extent that failure to satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect.

 

  (f)

ERISA

In respect of each Obligor, it:

 

  (i)

does not sponsor or participate in, or have any obligation to contribute to, or any liability under, any Plan or Multiemployer Plan; and

 

  (ii)

no ERISA Event has occurred or is reasonably expected to occur.

 

-58-

Plaquemines – Amended & Restated Common Terms Agreement


  (g)

Title

  (i)

Except as otherwise permitted under the Finance Documents and other than with respect to real property (which is covered under clause (m) (Real Property) below), each Obligor owns good and valid title to all of its property and assets included in the Collateral, free and clear of all Liens other than Permitted Liens, and the Security Documents are effective to create a legal, valid and enforceable Lien on, and security interest in, all of the Collateral, and the Secured Parties have a first priority perfected security interest in the Collateral (subject to Permitted Liens); and

 

  (ii)

No previous assignment of, or security interest in, any Obligor’s right, title and interest in any of the Collateral has been made or granted by any Obligor that remains in effect or is otherwise effective other than pursuant to the Finance Documents to which the Obligor is a party or in respect of Permitted Liens.

 

  (h)

Subsidiaries

The Pledgor has no Subsidiaries other than the Obligors and none of the Obligors has any Subsidiaries.

 

  (i)

Investment Company Act (Obligors)

In respect of each Obligor, it is not, and after giving effect to the issuance of the Senior Debt and the application of proceeds of the Senior Debt in accordance with the provisions of the Finance Documents shall not be, an “investment company” required to be registered under the Investment Company Act of 1940.

 

  (j)

Margin Stock

 

  (i)

No part of the proceeds of any Advance shall be used for the purpose of buying or carrying any Margin Stock or to extend credit to others for such purpose; and

 

  (ii)

in respect of each Obligor, it is not engaged in the business of extending credit for the purpose of purchasing or carrying Margin Stock, and no proceeds of any Senior Debt shall be used for any purpose that violates, or would be inconsistent with, Regulations T, U or X of the Federal Reserve Board.

 

  (k)

Minimum Insurance

Except as otherwise approved by the Insurance Advisor, any Minimum Insurances applicable to each of the Obligors are in full force and effect if required to be in effect at such time.

 

-59-

Plaquemines – Amended & Restated Common Terms Agreement


  (l)

No Loan Facility Declared Default or Event of Default

No Unmatured Loan Facility Event of Default, Loan Facility Event of Default or Loan Facility Declared Default has occurred and is Continuing.

 

  (m)

Real Property

 

  (i)

The Obligors collectively have good, legal and valid real property interests in the applicable portion of the Site pursuant to the Real Property Documents, in each case as is necessary for the Development at the time this representation and warranty is made;

 

  (ii)

The Obligors do not have any real property interests other than with respect to the Site or except as set forth on Schedule 5.2(m) (Real Property Interests);

 

  (iii)

No action has been commenced or is pending to terminate, restate or replace any Lease; and

 

  (iv)

To the Knowledge of each Obligor, there is no default or existing condition which with the giving of notice or passage of time or both would cause a default under a Lease, and all rents due under the Leases have been timely paid in full.

 

  (n)

Intellectual Property

The Obligors collectively own or have obtained and hold in full force and effect all material Intellectual Property that is necessary for carrying out the Development except for such items which are not required in light of the applicable stage of Development, and reasonably believe that they shall be able to obtain such items that are not owned or have not been obtained as of the date on which this representation and warranty is made or deemed repeated on or prior to the relevant stage of Development, provided that any such items shall not contain any material condition or material requirement that they do not expect to be able to satisfy without cost that could reasonably be expected to have a Material Adverse Effect.

 

  (o)

Anti-Corruption Laws

 

  (i)

None of the Obligors, or any of their Affiliates, nor, to the Knowledge of any of these entities, the Sponsor or any of its Affiliates, any of their respective directors, officers, agents, employees or other persons acting on behalf of them, is aware of or has taken any action, directly or indirectly, that would result in a violation by such entity of the Applicable Anti-Corruption Laws, Anti-Terrorism and Money Laundering Laws or Sanctions applicable to such Person; and

 

-60-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

the Obligors have instituted and maintain policies and procedures reasonably designed to ensure compliance therewith in all material respects.

 

  (p)

Collateral

The Collateral is subject to the perfected first priority Lien (subject only to Permitted Liens) established pursuant to the Security Documents.

 

  (q)

No Material Adverse Effect.

Since December 31, 2021, no event, circumstance or change has occurred (other than matters of a general economic nature) that has caused or evidenced, or could reasonably be expected to result in, a Material Adverse Effect.

 

  (r)

Accounts

Other than Authorized Investments held in accordance with the Common Security and Account Agreement, in respect of each Obligor, it does not have, and is not the beneficiary of, any bank account other than the Local Accounts, the Accounts and the Excluded Accounts.

 

  (s)

Material Project Agreements

 

  (i)

Each of the Material Project Agreements to which any Obligor is a party is in full force and effect to the Obligors’ Knowledge, and none of such Material Project Agreements has been terminated or otherwise amended, modified, supplemented, transferred, impaired or, to the Obligors’ Knowledge, assigned, except as permitted by the terms of the Finance Documents; and

 

  (ii)

no material default or event of default of any Obligor or, to the Knowledge of each Obligor, of any counterparty, have occurred and are continuing under any Material Project Agreement.

 

  (t)

Sufficiency of Funds

The Borrower reasonably believes that the Facility Debt Commitments and funds on deposit in the Construction Account, Contingency Reserve Account, the Phase 1 Pre-Completion Revenues Account, the Phase 2 Pre- Completion Revenues Account and the Permitted Finance Costs Reserve Account shall be sufficient to achieve the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain.

 

-61-

Plaquemines – Amended & Restated Common Terms Agreement


  (u)

Equity Interests and Ownership

The Equity Interests of each Obligor have been duly authorized and validly issued. There is no existing option, warrant, call, right, commitment or other agreement to which any Obligor is a party requiring, and there is no membership interest or other Equity Interests of Obligor outstanding which upon conversion or exchange would require, the issuance by any Obligor of any additional membership interests or other Equity Interests of any Obligor or other securities convertible into, exchangeable for or evidencing the right to subscribe for or purchase, a membership interest or other Equity Interests of any Obligor. The Obligors do not own any Equity Interests in any Person.

 

  (v)

Environmental Claims; Permit Notices

 

  (i)

Except as set forth in Schedule G (Disclosure Schedule) hereto, there is:

 

  (A)

no Environmental Claim now pending or, to the Knowledge of each Obligor, threatened against it or the Project Facilities, or expressly with respect to its Permits or the Development, that in each case could reasonably be expected to have a Material Adverse Effect; and

 

  (B)

no existing default by it under any applicable order, writ, injunction or decree of any Governmental Authority or arbitral tribunal with respect to Environmental Claims that could reasonably be expected to have a Material Adverse Effect; and

 

  (ii)

In respect of each Obligor, it has not received any notice from any Governmental Authority asserting that any information set forth in any application submitted by or on behalf of it in connection with any material Permit that has been obtained as of the date this representation is made or deemed repeated was inaccurate or incomplete at the time of submission that could reasonably be expected to have a Material Adverse Effect.

 

-62-

Plaquemines – Amended & Restated Common Terms Agreement


  (w)

Tax Status

In respect of each Obligor, it is a limited liability company that is treated as a partnership for U.S. federal income tax purposes or an entity disregarded for U.S. federal income tax purposes as separate from its owner and not an association taxable as a corporation, and neither the execution or delivery of any Transaction Document nor the consummation of any of the transactions contemplated thereby shall affect such status.

 

  (x)

Easements; Utilities; Services

All easements, leasehold and other real property interests, and all utility and other services, means of transportation, facilities, other materials and other related rights, that are necessary for the operation and maintenance of the Project, as currently conducted (and in light of the current status of Development), in accordance in all material respects with all applicable Government Rules and the Transaction Documents (including, to the extent applicable, gas, electrical, water and sewage services and facilities) are available to the applicable Obligor or, if not then available, are reasonably expected to be available to the applicable Obligor as and when needed for the operation and maintenance of the Project Facilities.

 

  (y)

Development

No other material contracts are necessary for the Development of the Project Facilities at their respective current stages of development other than the Material Project Agreements in effect.

 

  (z)

Affected Financial Institutions

As of the Upsize Closing Date, no Obligor is an Affected Financial Institution.

 

6.

INCURRENCE OF ADDITIONAL SENIOR DEBT

 

  6.1

Permitted Senior Debt

 

  (a)

The Borrower may from time to time enter into agreements to incur, and may incur, Senior Debt Obligations in addition to the Upsized Senior Debt Obligations that, for so long as the Common Terms Agreement remains in effect in accordance with its terms, consist only of Working Capital Debt and/or Replacement Debt (and shall satisfy the requirements of this Article 6 (Incurrence of Additional Senior Debt) applicable to such category of Senior Debt).

 

  (b)

Each Senior Creditor Group Representative (on behalf of the Senior Creditors providing Additional Senior Debt) must accede to the Common Security and Account Agreement pursuant to, and in accordance with, the conditions set forth in Section 2.7 (Accession of Senior Creditor Group Representatives) of the Common Security and Account Agreement.

 

-63-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

Incurrence of Additional Senior Debt under one Section of this Article 6 (Incurrence of Additional Senior Debt) shall not preclude the incurrence of Additional Senior Debt under any other Section of this Article 6 (Incurrence of Additional Senior Debt), and the failure of the proposed Additional Senior Debt to meet the requirements of one Section of this Article 6 (Incurrence of Additional Senior Debt) shall not preclude the incurrence of such Additional Senior Debt if permitted under other Sections of this Article 6 (Incurrence of Additional Senior Debt).

 

  (d)

Additional Senior Debt under this Article 6 (Incurrence of Additional Senior Debt) may be incurred under this Agreement and/or any other Senior Debt Instrument.

 

  6.2

Working Capital Debt

 

  (a)

The Borrower may incur senior secured, subordinate or unsecured Indebtedness (which, if secured on a pari passu basis, shall constitute Senior Debt) not exceeding an amount outstanding at any one time equal to the sum of:

 

  (i)

an aggregate principal amount not to exceed the amount of the Working Capital Facility as of the Upsize Closing Date; and

 

  (ii)

$500,000,000;

in each case outstanding in the aggregate at any one time under one or more working capital and/or letter of credit facilities (including, without limitation, the Working Capital Facility) (collectively, the “Working Capital Debt”) (x) (1) prior to the Project Phase 1 Completion Date, to satisfy the Obligors’ obligations related to purchases of natural gas and any costs and expenses related to the supply or transport of natural gas by the Obligors (including for testing or operations) including credit support (and mark to market) obligations in connection therewith, (2) after the Project Phase 1 Completion Date and prior to the Project Phase 2 Completion Date, (A) an amount equal to $1.0 billion (the “P2 WCF Sublimit”), to satisfy the Obligors’ obligations related to purchases of natural gas and any costs and expenses related to the supply or transport of natural gas by the Obligors (including for testing or operations) including credit support (and mark to market) obligations in connection therewith, and (B) the remainder, for any working capital purposes of the Obligors and (3) after the Project Phase 2 Completion Date, working capital purposes of the Obligors and (y) to fund reserve requirements, as the case may be, so long as:

 

-64-

Plaquemines – Amended & Restated Common Terms Agreement


  (I)

the all-in yield (whether in the form of interest rate margins, original issue discount (“OID”) or upfront fees) applicable to any additional Working Capital Facility will not be more than 0.25% higher than the corresponding all-in yield (giving effect to interest rate margins, OID, upfront fees and interest rate floors) for the then-existing Working Capital Facility unless the interest rate margins with respect to such then-existing Working Capital Facility are increased by an amount equal to the difference between the all-in yield with respect to the additional Working Capital Facility and the corresponding all-in yield on the then-existing Working Capital Facility; provided, further, that, in determining the all-in yield applicable to the foregoing (x) customary arrangement, underwriting, amendment or commitment fees payable to one or more arrangers shall be excluded, (y) OID and upfront fees paid to the lenders shall be included (with OID and upfront fees being equated to interest based on assumed four- year life to maturity or, if shorter, the actual weighted average life to maturity), and (z) if the new Working Capital Facility includes an interest rate floor greater than the applicable interest rate floor under the then- existing Working Capital Facility, such differential between interest rate floors shall be equated to an increase in the applicable interest rate margin with respect to such Working Capital Facilities for purposes of determining whether an increase to the interest rate margin under the existing Working Capital Facility shall be required, but only to the extent an increase in the interest rate floor in the existing Working Capital Facility would cause an increase in the interest rate then in effect thereunder, and in such case the interest rate floor (but not the interest rate margin) applicable to the existing Working Capital Facility shall be increased to the extent of such differential between interest rate floors; and

 

  (II)

provided that the Borrower certifies that:

 

  (A)

no Event of Default or Unmatured Event of Default:

 

  (1)

has occurred and is Continuing; or

 

  (2)

could reasonably be expected to occur after giving effect to the incurrence of the Working Capital Debt;

 

  (B)

any Senior Debt Instrument governing the Working Capital Debt shall require the Borrower to reduce the principal amount relating to any revolving Loans thereunder to $0 for a period of at least five (5) consecutive Business Days at least once per calendar year; provided that this requirement shall not apply to letters of credit outstanding or Loans outstanding as a result of a draw under a letter of credit; provided further that amounts may not be borrowed under any one Facility Agreement for Working Capital Debt in order to meet this requirement under any other Facility

 

-65-

Plaquemines – Amended & Restated Common Terms Agreement


  Agreement for Working Capital Debt (it being acknowledged and agreed that the foregoing shall not limit the utilization by the Borrower of other Indebtedness that is permitted to be incurred pursuant to Section 12.14 (Limitation on Indebtedness) for such purposes to the extent the terms and conditions of such Indebtedness permit such utilization); and

 

  (C)

the Intercreditor Agent has received, at least three Business Days before the incurrence of any such Working Capital Debt, a certificate from the Borrower that:

 

  (1)

identifies each Senior Creditor Group Representative for, and each holder of, any such Working Capital Debt; and

 

  (2)

attaches a copy of each proposed Senior Debt Instrument relating to any such Working Capital Debt.

 

  (b)

Any provider of Working Capital Debt (or a Senior Creditor Group Representative on its behalf) that is secured shall accede as a Senior Creditor to the Common Security and Account Agreement, the Intercreditor Agreement and this Agreement, and shall share pari passu in the Collateral.

 

  6.3

Replacement Debt

 

  (a)

At any time and from time to time, the Borrower may incur additional senior secured, subordinate or unsecured Indebtedness (which, if secured on a pari passu basis, shall constitute Senior Debt) or enter into agreements with Persons who commit to provide additional Indebtedness in order to prepay or repay Senior Debt and/or replace all or part of the Facility Debt Commitments under one or more Loans (“Replacement Debt”), as the case may be, so long as and provided that the Borrower certifies that:

 

  (i)

the Replacement Debt, taken as a whole:

 

  (A)

has a weighted average life no less than the then-remaining weighted average life of that of the Senior Debt or the Facility Debt Commitments being prepaid or replaced, taken as a whole;

 

  (B)

has a Final Maturity Date no earlier than the Senior Debt or the Facility Debt Commitments being prepaid or replaced; and

 

-66-

Plaquemines – Amended & Restated Common Terms Agreement


  (C)

may not be voluntarily prepaid or redeemed prior to having repaid the then-outstanding Term Loans in full and having cancelled all outstanding Term Loan Commitments;

 

  (ii)

the Replacement Debt is incurred solely for the permitted prepayment, in whole or in part, of existing Senior Debt (and provisions, costs, prepayment premiums, fees or expenses associated with the Replacement Debt or the prepaid Senior Debt, as applicable (including, without duplication, (A) any Hedging Termination Amount with respect to any Permitted Hedging Instrument subject to the refinancing with the proposed Replacement Debt; (B) any amounts required to be deposited in a debt service reserve or similar reserve (or any interest during construction) account in connection with the issuance of such Replacement Debt; (C) upfront fees and/or original issue discount on, and transaction expenses relating to, such Replacement Debt; and (D) any incremental carrying costs of such Replacement Debt (including any increased interest during construction) associated with any such cancellation, prepayment or redemption, or incurred in connection with the proposed Replacement Debt)) or the permitted replacement of existing unutilized commitments of a Senior Creditor Group (or, within a Senior Creditor Group, of any Facility Lender);

 

  (iii)

the aggregate principal amount of Replacement Debt incurred or committed and then available does not exceed the aggregate amount of the Senior Debt or the Facility Debt Commitments being prepaid or replaced, together with any premiums, costs, fees or expenses associated with the Replacement Debt (including those described in sub-clause (ii) above and clause (b) below);

 

  (iv)

the Borrower will have demonstrated by delivery of an updated Base Case Forecast (prepared in accordance with the Base Case Sizing Criteria) that the incurrence of the Replacement Debt shall not result in a Fixed Projected DSCR of less than 1.40:1 commencing on the first CTA Payment Date following such prepayment (but in all cases, after the First Repayment Date) for each twelve (12) month period thereafter (including any stub period) through the Qualifying Term of the Qualifying LNG SPAs then in effect (with such ratio being calculated on a pro forma basis giving effect to the incurrence of the Replacement Debt and the prepayment or repayment of the existing Senior Debt or cancellation of the Facility Debt Commitments);

 

-67-

Plaquemines – Amended & Restated Common Terms Agreement


  (v)

the Replacement Debt (A) is ranked pari passu and is treated pro rata in all respects with Senior Debt, and does not benefit from any security or guarantee from the Collateral Parties that is in addition to any security or guarantee from such Persons provided in respect of any then-outstanding Senior Debt (including any Senior Debt Commitments thereunder) unless such security or guarantee is provided for the equal and ratable benefit of each Senior Creditor or (B) is subordinated or unsecured;

 

  (vi)

the Replacement Debt does not benefit from any material covenants or terms (excluding pricing or optional prepayment or redemption terms) that are materially more restrictive on the Obligors than those included in this Agreement unless such covenants or terms are provided for the benefit of all Facility Lenders;

 

  (vii)

simultaneously with the incurrence of any Replacement Debt that occurs on or after the date by which the Borrower is required to fund the Senior Facilities Debt Service Reserve Account in accordance with Section 4.5(i) (Deposits and Withdrawals – Senior Facilities Debt Service Reserve Account) of the Common Security and Account Agreement, the Borrower shall use a portion of the proceeds of such Replacement Debt to fund any increase in the then- applicable Senior Facilities Reserve Amount or, if such Replacement Debt does not constitute Facility Debt Obligations, fund any Additional Debt Service Reserve Account opened by the Borrower in accordance with the Common Security and Account Agreement that was established for such Replacement Debt in an amount as required by such Replacement Debt; and

 

  (viii)

the Intercreditor Agent has received (A) at least three Business Days prior to the incurrence of such Replacement Debt, (1) a notice describing the then-anticipated principal terms and conditions of the proposed Replacement Debt (other than, in the case of Replacement Debt comprised of Senior Notes, the pricing and amortization schedule of such Senior Notes, which shall be provided when they become available) and (2) the substantially agreed forms of the finance documents relating to any proposed Replacement Debt (other than in the case of Replacement Debt comprised of Senior Notes) and (B) on the date of the incurrence of such Replacement Debt, (1) an updated notice describing the final principal terms and conditions of the Replacement Debt (including, in the case of Replacement Debt comprised of Senior Notes, the pricing and amortization schedule of such Senior Notes), (2) copies of the executed finance documents relating to the Replacement Debt and (3) an officer’s certificate of the Obligors certifying to the matters set forth in clauses (i)-(vii) above;

 

-68-

Plaquemines – Amended & Restated Common Terms Agreement


provided, in each case, that no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing or could reasonably be expected to occur after giving effect to the incurrence of the Replacement Debt. Any provider of Replacement Debt (or a Senior Creditor Group Representative on its behalf) shall accede as a Senior Creditor to the Common Security and Account Agreement and, if a Facility Lender, the Intercreditor Agreement and this Agreement, and shall share pari passu or on a junior basis in the Collateral or on an unsecured basis.

 

  (b)

Within 30 days after the first Advance of any Replacement Debt, the Borrower shall pay, from the proceeds of the Replacement Debt or other cash flow available for such purpose, any Funding Losses and/or other amounts required to be paid in accordance with Section 3.6 (Prepayment Fees and Funding Losses) and the applicable Facility Agreement with respect to the Facility Debt Commitments being replaced.

 

7.

PERMITTED DEVELOPMENT EXPENDITURES/EXPANSIONS

 

  7.1

Permitted Development Expenditures

 

  (a)

The Obligors shall not make any Development Expenditures that do not qualify as Permitted Development Expenditures. Assets or property built or acquired with Development Expenditures shall constitute Collateral except as provided in the Security Documents.

 

  (b)

For the avoidance of doubt, (i) Permitted Development Expenditures may be made prior to the Project Phase 2 Completion Date to the extent permitted under Article 9 (Material Construction Contracts) and (ii) Permitted Development Expenditures may also be made in relation to an Expansion to the extent permitted under Section 7.2 (Expansion Contracts).

 

  7.2

Expansion Contracts

The Obligors shall not enter into a construction contract or contracts with respect to the development of any mixed refrigerant liquefaction blocks, modules and supporting facilities in addition to the Project Facilities, and related loading, transportation and storage facilities, in addition to the Development then in operation or under construction (an “Expansion”) that contain obligations and liabilities of any Obligor, which, in the aggregate, are in excess of $750 million without the prior consent of the Intercreditor Agent acting at the instruction of the Requisite Intercreditor Parties (not to be unreasonably withheld, conditioned or delayed); provided that without such consent the Obligors may:

 

-69-

Plaquemines – Amended & Restated Common Terms Agreement


  (a)

conduct front-end engineering, development and design work using Equity Funding not otherwise committed to other expenditures for the Development;

 

  (b)

prepare and submit applications for Permits related to any such Expansion;

 

  (c)

undertake pre-construction activities and early works activities associated with an Expansion; and

 

  (d)

enter into one or more contracts or agreements in respect of any Expansion so long as any such expenditures do not have any material impact on the construction or operations of the Phase 1 Project Facilities or the Phase 2 LNG Facility;

provided that, the cost of all obligations and liabilities in respect of any Expansion and the activities described in sub-clauses (a) through (d) above that are undertaken by the Obligors (or in respect of which an Obligor has obligations or liabilities) shall be pre-funded into the Excess Equity Proceeds Account in accordance with the Common Security and Account Agreement, in each case as expressly permitted under the Finance Documents and which use for the contemplated development (i) could not reasonably be expected to have a Material Adverse Effect and (ii) in the case of the activities described in sub-clauses (c) and (d) to the extent undertaken at the Site, could not reasonably be expected to impair, delay or adversely affect the Development in any material respect (as certified by the Independent Engineer).

 

8.

LNG SPA COVENANTS

 

  8.1

LNG SPA Maintenance

 

  (a)

The Borrower shall maintain Qualifying LNG SPAs providing for commitments to purchase LNG in quantities at least equal to the then applicable Base Committed Quantity for a Qualifying Term unless one or more of such Qualifying LNG SPAs has terminated, in which case the Borrower shall enter into a replacement Qualifying LNG SPA (and, in the case of any DPU LNG SPA permitted hereunder, shipping arrangements relating thereto in accordance with Schedule BB (Shipping Agency Term Sheet)) within 90 days following such termination to the extent necessary to meet the then applicable Base Committed Quantity; provided that the Borrower shall have a further 90 days to enter into such a replacement Qualifying LNG SPA (and, in the case of any DPU LNG SPA permitted hereunder, shipping arrangements relating thereto) if the following two conditions are met:

 

  (i)

the Borrower intends to replace such terminated Qualifying LNG SPA with an LNG SPA that would be a Qualifying LNG SPA that causes the Obligors to meet the then applicable Base Committed Quantity and is diligently pursuing such replacement; and

 

-70-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

the termination of such Qualifying LNG SPA could not reasonably be expected to result in a Material Adverse Effect;

and the Intercreditor Agent has received a certification from the Borrower confirming that each such condition above has been met prior to the expiration of the initial 90 day period together with documentation reasonably supporting its certification, which may include, to the extent relevant and applicable, a description of the plans being undertaken and expected schedule for replacement of the terminated Qualifying LNG SPA (although commercially sensitive information may be omitted), any measures being taken by the Borrower to address the underlying cause of the termination to the extent relevant to the termination and the replacement process, any interim cash flow mitigation measures being taken by the Borrower (including sales of spot cargoes) and the impact on the Borrower’s projected Cash Flow during the subsequent cure period.

For the avoidance of doubt, the Qualifying LNG SPAs required to be maintained in accordance with the provisions of this Section 8.1 (LNG SPA Maintenance) are referred to as “Required LNG SPAs”.

 

  (b)

A “Qualifying LNG SPA” includes each of the Initial LNG SPAs, any LNG SPA (and, in the case of any DPU LNG SPA permitted hereunder, shipping arrangements relating thereto) entered into for a Qualifying Term in accordance with Section 8.4(a) (Sale of Supplemental Quantity), and any other LNG SPA that meets each of the following conditions, in each case, other than the Excess Capacity LNG SPAs:

 

  (i)

such LNG SPA is entered into for a Qualifying Term with:

 

  (A)

an Investment Grade LNG Buyer (or guaranteed by an Investment Grade entity);

 

  (B)

in the case of any LNG SPA that is a replacement of an LNG SPA referenced in clauses (c), (d) or (f) of the definition of “Phase 1 Initial LNG SPAs” or in clauses (c) or (e) of the definition of “Phase 2 Initial LNG SPAs”, (i) an Investment Grade LNG Buyer (or guaranteed by an Investment Grade entity) or (ii) an entity with consolidated net tangible assets of at least $15 billion (or guaranteed by an entity with such consolidated net tangible assets);

 

-71-

Plaquemines – Amended & Restated Common Terms Agreement


  (C)

in the case of any LNG SPA entered into in accordance with Section 8.4(a) (Sale of Supplemental Quantity) or any LNG SPA that is a replacement of an LNG SPA referenced in clauses (a), (b), or (e) of the definition of “Phase 1 Initial LNG SPAs” or clauses (a), (b), (d), (f) or (g) of the definition of “Phase 2 Initial LNG SPAs”, so long as the Borrower has other Qualifying LNG SPAs for at least the then applicable Base Committed Quantity with counterparties that are an Investment Grade LNG Buyer (or guaranteed by an Investment Grade entity), an entity with consolidated net tangible assets of at least $3 billion per 1.0 MTPA of ACQ (or guaranteed by an entity with such consolidated net tangible assets); or

 

  (D)

any other entity approved by the Intercreditor Agent;

 

  (ii)

delivery of LNG under such LNG SPA is on an FOB basis or, subject to the DPU LNG SPA Quantity Restrictions, on a DPU basis pursuant to a DPU LNG SPA;

 

  (iii)

the Borrower has delivered to the Intercreditor Agent notice of the proposed terms of such LNG SPA; and

 

  (A)

 

  (1)

(x) in the case of any LNG SPA that is a replacement of a Required LNG SPA, such terms are no less favorable than and (y) in the case of any new LNG SPA, such terms are on material commercial terms no less favorable than, in each case, those set forth in any Qualifying LNG SPA then in effect or in the case of any DPU LNG SPA and subject to the DPU LNG SPA Quantity Restrictions is supported by shipping arrangements having terms substantially consistent with those specified in Schedule BB (Shipping Agency Term Sheet); or

 

  (2)

the Intercreditor Agent confirms that the Requisite Intercreditor Parties, after consultation with the Market Consultant, are reasonably satisfied with the terms of such LNG SPA, including its conformity to Market Terms;

 

-72-

Plaquemines – Amended & Restated Common Terms Agreement


  (iv)

the execution of such LNG SPA and performance by the Borrower of its obligations under such LNG SPA shall not result in a breach of any Qualifying LNG SPA then in effect, or any Required Export Authorization then in effect and no additional Required Export Authorizations are necessary in connection with the execution of such LNG SPA; and

 

  (v)

the Borrower has delivered to the Intercreditor Agent a certificate certifying to the matters set forth in clauses (i), (ii), (iii)(A)(1) (if applicable) and (iv) above.

 

  8.2

LNG SPA Mandatory Prepayment

 

  (a)

The Borrower shall be required to make a mandatory prepayment (an “LNG SPA Mandatory Prepayment”) if either of the events set forth below occurs (each, an “LNG SPA Prepayment Event”):

 

  (i)

the Borrower breaches the covenant in Section 8.1 (LNG SPA Maintenance) (taking into account the period set forth therein to replace the relevant LNG SPA); or

 

  (ii)

with respect to any Required LNG SPA, a Required Export Authorization becomes Impaired and the Borrower does not:

 

  (A)

provide a reasonable remediation plan (setting forth in reasonable detail proposed steps to reinstate the Required Export Authorization or to modify its LNG SPA arrangements, such as through lawful diversions by the counterparty thereto and/or alternative delivery or sale arrangements, such that such Impaired Export Authorization is no longer a Required Export Authorization with respect to any or all such Required LNG SPAs (each such item, an “Export Authorization Remediation”)) within 30 days following such occurrence;

 

  (B)

diligently pursue such Export Authorization Remediation; or

 

  (C)

cause such Export Authorization Remediation to take effect within 90 days following the occurrence of the Impairment; provided that the Borrower shall have a further 90 days to effect an Export Authorization Remediation if the following two conditions are met:

 

  (1)

the Borrower is diligently pursuing its plan for the Export Authorization Remediation; and

 

  (2)

the Impairment of the Required Export Authorization of such Required LNG SPA could not reasonably be expected to result in a Material Adverse Effect during such subsequent cure period;

 

-73-

Plaquemines – Amended & Restated Common Terms Agreement


and the Intercreditor Agent has received a certification from the Borrower confirming that each such condition above has been met prior to the expiration of the initial 90 day period together with documentation reasonably supporting its certification, which may include, to the extent relevant and applicable, a description of the plans being undertaken for the Export Authorization Remediation (although commercially sensitive information may be omitted), any measures being taken by the Borrower to address the underlying cause of the Impairment to the extent relevant to the Impairment and Export Authorization Remediation, any legal measures being undertaken to reverse the Impairment, any interim cash flow mitigation measures being taken by the Borrower (including sales of spot cargoes), any modification to LNG SPA arrangements such that the Impaired Export Authorization is no longer a Required Export Authorization with respect to any or all such Required LNG SPAs, and the impact on the Borrower’s projected Cash Flow during the subsequent cure period, and the Intercreditor Agent (acting on the instructions of the Requisite Intercreditor Parties), acting reasonably, has not objected to such certification within 30 days following delivery thereof.

 

  (b)

The amount of the Senior Debt (which shall not extend to any Working Capital Debt unless only Working Capital Debt remains outstanding) that the Borrower shall repay and the amount of undrawn Facility Debt Commitments (which shall not include any Working Capital Debt unless only Working Capital Debt remains outstanding) that the Borrower shall cancel upon the occurrence of any LNG SPA Prepayment Event shall be an amount equal to:

 

  (i)

the aggregate principal amount of Senior Debt then outstanding plus the aggregate principal amount of undrawn Facility Debt Commitments; less

 

  (ii)

the maximum amount of Senior Debt that can remain outstanding consistent with the Base Case Sizing Criteria based on the Base Case Forecast and updated to take into account each Qualifying LNG SPA then in full force and effect (after giving effect to the LNG SPA Prepayment Event) and including any new Qualifying LNG SPAs entered into by the Borrower to replace an LNG SPA the termination of which triggered the LNG SPA Prepayment Event.

 

-74-

Plaquemines – Amended & Restated Common Terms Agreement


The Borrower shall provide to the Intercreditor Agent reasonable documentary support to show the amount of Senior Debt to be repaid and Senior Debt Commitments to be cancelled, including the Base Case Sizing Criteria and the updated Base Case Forecast and, to the extent appropriate, the Required LNG SPAs then in effect and reasonable background information regarding Required Export Authorizations with respect to such Required LNG SPAs and supporting the designation of such Export Authorizations as Required Export Authorizations with respect to such Required LNG SPAs.

 

  (c)

In making the prepayment and cancellation described in clause (b) above, the Borrower shall first repay the aggregate principal amount of Senior Debt Obligations then outstanding to the extent required under this Section 8.2 (LNG SPA Mandatory Prepayment) or until there are no more Senior Debt Obligations outstanding and if this has not resulted in a prepayment of the amount required to satisfy the test in clause (b) above, shall second cancel the aggregate principal amount of Facility Debt Commitments to the extent required under this Section 8.2 (LNG SPA Mandatory Prepayment). The prepayment and cancellation made pursuant to this Section 8.2 (LNG SPA Mandatory Prepayment) shall be required to be made by the earliest of (i) the 30th day following the termination of the cure period applicable thereto, (ii) the next Quarterly Payment Date if such date is more than 10 Business Days following the termination of the cure period applicable thereto and (iii) the 10th Business Day following the termination of the cure period applicable thereto if the next Quarterly Payment Date is less than 10 Business Days following the termination of the cure period applicable thereto.

 

  (d)

Upon completion of the prepayment of Senior Debt and cancellation of Facility Debt Commitments as and to the extent required by clause (b) and (c) above, the LNG SPA Prepayment Event and underlying breach of Section 8.1 (LNG SPA Maintenance) or Impairment triggering that LNG SPA Prepayment Event shall no longer be continuing under the Finance Documents in so far as the same set of events, facts or circumstances that caused such breach, Impairment and mandatory prepayment are concerned, but without prejudice to the Borrower’s obligations under Section 8.1 (LNG SPA Maintenance) and Section 8.2 (LNG SPA Mandatory Prepayment) with respect to any other event, fact or circumstance.

 

-75-

Plaquemines – Amended & Restated Common Terms Agreement


  8.3

Amendment of LNG SPAs

The Borrower shall not agree to:

 

  (a)

any amendment or modification of the price or quantity provisions of any Qualifying LNG SPA that results in a reduction of the price or quantity:

 

  (i)

if such amendment or modification results in a breach of Section 8.1 (LNG SPA Maintenance); or

 

  (ii)

unless after giving effect to such amendment or modification, the Fixed Projected DSCR starting after the first CTA Payment Date for the repayment of principal following the later of the Project Phase 1 Completion Date and the date of such amendment or modification and for each calendar year thereafter through the Qualifying Term of the Qualifying LNG SPAs then in effect is at least the Upsize Closing Date DSCR;

 

  (b)

any amendment or modification of any Qualifying LNG SPA that:

 

  (i)

could reasonably be expected to have a Material Adverse Effect;

 

  (ii)

would not be on Market Terms; or

 

  (iii)

would otherwise violate or conflict with the terms of the Finance Documents;

 

  (c)

any material waiver, amendment or modification of the governing law, choice of forum, responsibility for shipping (i.e., FOB, DPU or delivery ex- ship/delivered-at-terminal basis) (subject to the ability of the Borrower to replace (i) only to the extent such replacement would be permitted under the DPU LNG SPA Quantity Restrictions, an LNG SPA that is on a FOB basis with a DPU LNG SPA or (ii) an LNG SPA that is on a DPU basis with an LNG SPA that is on an FOB basis), term (other than an increase), or guarantee or credit support provisions (other than an increase or improvement) of any Qualifying LNG SPA, in each case if within 60 days following notice of such proposed amendment or modification, the Intercreditor Agent notifies the Borrower in writing of its objection to such proposed amendment or modification; or

 

  (d)

any amendment or modification of the material elements of the structure or components of the pricing formula or the methodology of calculating the Contract Sales Price or any material term defining the “take-or-pay” obligations of any Qualifying LNG SPA (other than any increase or improvement thereof), in each case, if within 60 days following notice of such proposed amendment or modification, the Intercreditor Agent notifies the Borrower in writing of its objection to such proposed amendment or modification.

 

-76-

Plaquemines – Amended & Restated Common Terms Agreement


  8.4

Sale of Supplemental Quantity

 

  (a)

The Borrower shall be permitted to enter into LNG SPAs (and, in the case of any DPU LNG SPA permitted hereunder, shipping arrangements relating thereto) in respect of all or any portion of the Supplemental Quantity, which LNG SPAs may be of any duration, on any terms and to buyers of any credit quality; provided that:

 

  (i)

the Required LNG SPAs are then in full force and effect;

 

  (ii)

either (A) such LNG SPA has a term that is less than 5 years (measured from the Commercial Operation Date thereunder) or (B) such LNG SPA is entered into with (1) an Initial LNG Buyer, (2) an Investment Grade LNG Buyer (or guaranteed by an Investment Grade entity), (3) an entity with consolidated net tangible assets of at least $3 billion per 1.0 MTPA of ACQ (or guaranteed by an entity with such consolidated net tangible assets) or (4) any other entity approved by the Intercreditor Agent;

 

  (iii)

each buyer thereunder is instructed to pay the contract sales price to the Phase 1 Pre-Completion Revenues Account, Phase 2 Pre- Completion Revenues Account or the Revenue Account as required by Section 8.6 (Payment of LNG Sales Proceeds);

 

  (iv)

the performance by the Borrower of its obligations under such LNG SPAs could not reasonably be expected to have a material adverse effect on the ability of the Borrower to perform its obligations under the Required LNG SPAs;

 

  (v)

such LNG SPA is on Market Terms;

 

  (vi)

the entry into and the terms of such LNG SPA shall not result in a breach or default of any Required LNG SPA then in effect or the Impairment of any then-required material Permit;

 

  (vii)

[reserved]; and

 

  (viii)

delivery of LNG under such LNG SPA is on an FOB basis or, subject to the DPU LNG SPA Quantity Restrictions, on a DPU basis pursuant to a DPU LNG SPA (subject to the ability of the Borrower to replace an LNG SPA that is on a FOB basis with a DPU LNG SPA).

 

-77-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

The Borrower shall be permitted to enter into the Excess Capacity LNG SPAs and any other LNG SPAs or replacements thereof in respect of all or any portion of the Excess Capacity Quantity, which LNG SPAs may be of any duration, on any terms and to buyers of any credit quality.

 

  8.5

Sale of Pre-Completion Quantities

 

  (a)

The Borrower shall be permitted to enter into LNG SPAs (and, in the case of any DPU LNG SPA permitted hereunder, shipping arrangements relating thereto) in respect of any LNG produced or to be produced by the Phase 1 LNG Facility prior to the Project Phase 1 Completion Date or by the Phase 2 LNG Facility prior to the Project Phase 2 Completion Date (“Pre- Completion Quantities”), which LNG SPAs may be of any duration, on any terms and to buyers of any credit quality; provided that:

 

  (i)

the Required LNG SPAs are then in full force and effect and, following the Project Phase 1 Completion Date, such LNG SPA in respect of Pre-Completion Quantities could not reasonably be expected to adversely affect in any material respect the Borrower’s ability to perform its obligations under the Phase 1 Initial LNG SPAs (as certified to the Intercreditor Agent by an Authorized Officer of the Borrower);

 

  (ii)

such LNG SPA has a term that ends no later than the day immediately preceding the Commercial Operation Date (as defined in each such LNG SPA);

 

  (iii)

each buyer thereunder is instructed to pay the contract sales price (the “Pre-Completion Revenues”) to the Phase 1 Pre-Completion Revenues Account or the Phase 2 Pre-Completion Revenues Account as required by Section 8.6 (Payment of LNG Sales Proceeds);

 

  (iv)

the performance by the Borrower of its obligations under such LNG SPAs could not reasonably be expected to have a material adverse effect on the ability of the Borrower to perform its obligations under the Required LNG SPAs;

 

  (v)

the entry into and the terms of such LNG SPA shall not result in a breach or default of any Required LNG SPA then in effect or the Impairment of any then-required material Permit; and

 

  (vi)

delivery of LNG under such LNG SPA is on an FOB basis or on a DPU basis pursuant to a DPU LNG SPA (without any restriction on the quantity of Pre-Completion Quantities that may be sold pursuant to DPU LNG SPAs).

 

-78-

Plaquemines – Amended & Restated Common Terms Agreement


  8.6

Payment of LNG Sales Proceeds

The Borrower shall irrevocably instruct each LNG Buyer to pay the proceeds of sales of LNG under its LNG SPAs directly into:

 

  (a)

for any payments made (i) with respect to an LNG SPA in respect of the Phase 1 LNG Facility prior to the Project Phase 1 Completion Date, the Phase 1 Pre-Completion Revenues Account or (ii) with respect to any LNG SPA in respect of the Phase 2 LNG Facility prior to the Project Phase 2 Completion Date, the Phase 2 Pre-Completion Revenues Account; and

 

  (b)

for any payments made (i) with respect to an LNG SPA in respect of the Phase 1 LNG Facility on or after the Project Phase 1 Completion Date or (ii) with respect to an LNG SPA in respect of the Phase 2 LNG Facility on or after the Project Phase 2 Completion Date, the Revenue Account.

 

  8.7

DPU Shipping Agreement

The Borrower shall, within on or before September 30, 2023, enter into a Shipping Agency Agreement, by and between the Borrower and Venture Global Commodities, LLC, documenting shipping arrangements with respect to any DPU LNG SPA permitted hereunder, substantially consistent with the terms set forth in Schedule BB (Shipping Agency Term Sheet).

 

9.

MATERIAL CONSTRUCTION CONTRACTS

 

  9.1

Change Orders

Other than with respect to any Change Order specified in Schedule I (Change Orders) hereto, the Obligors shall not agree to:

 

  (a)

initiate or consent to (without the consent of the Intercreditor Agent acting in consultation with and in reliance on the applicable certificates from the Independent Engineer as to items (i) through (vi) below) any Change Order that:

 

  (i)

increases the contract price of a Material Construction Contract from that in effect on the Upsize Closing Date or increases the aggregate anticipated Project Costs of the Project Facilities in excess of the costs contemplated by the Construction Budget and Schedule; provided that: the Obligors may, without the consent of the Intercreditor Agent (or delivery of any certificate from the Independent Engineer) and subject to sub-clauses (ii) through (vi) below, enter into any Change Order under any Material Project Agreement or other contract if:

 

-79-

Plaquemines – Amended & Restated Common Terms Agreement


  (A)

the amount of any such Change Order is less than $75 million individually and the aggregate of all such Change Orders or payments with respect to the Material Project Agreements and/or other contracts (taken together), is less than $450 million collectively in each case, measured for Change Orders to be entered into after the Upsize Closing Date; and

 

  (B)

(I) such Change Order does not, individually or when taken together with all other Change Orders, exceed the Contingency Reserve Amount (as such amount is replenished with any deposits into the Contingency Reserve Account) of the Common Security and Account Agreement; or (II) if the Change Orders are paid for in connection with any reallocation of aggregate contingency or application of cost savings from any line item in the Construction Budget and Schedule, then the Obligors may, without the consent of the Intercreditor Agent and subject to sub-clauses (ii) through (vi) below, enter into a Change Order to make payment of any claim under such Material Project Agreements and/or other contracts;

 

  (ii)

modifies any credit support requirements, warranty, Performance Liquidated Damages or Delay Liquidated Damages or Schedule Bonus under any Material Project Agreement in a manner that is materially adverse to the Obligors or the Secured Parties;

 

  (iii)

changes the scope of work or performance testing standards under any Material Project Agreement in a manner materially adverse to the Obligors;

 

  (iv)

delays the Facility Substantial Completion Deadline (as defined in the Phase 1 EPC Contract or the Phase 2 EPC Contract, as applicable) by more than 60 days;

 

  (v)

results in the revocation or adverse modification of any material Permit; or

 

  (vi)

could reasonably be expected to result in a Material Adverse Effect.

 

-80-

Plaquemines – Amended & Restated Common Terms Agreement


  9.2

UOP Pre-Treatment Systems

 

  (a)

No Obligor shall agree to any Change Order that modifies the basis of design of the pre-treatment systems supplied by UOP pursuant to the Phase 1 Pretreatment Contract that would require subsequent changes to the basis of design for the equipment delivered under any of the Phase 1 LTS Purchase Order, the PIS 2021 Purchase Order or the PIS 2022 Purchase Order unless the Borrower delivers together with such Change Order a written confirmation from BHES that such modification does not affect any performance guarantee (including any minimum performance guarantee or unconditional performance obligation under either the Phase 1 LTS Purchase Order, the PIS 2021 Purchase Order or the PIS 2022 Purchase Order), in which event such Change Order shall be permitted (subject to Section 9.1 (Change Orders)).

 

  (b)

No Obligor shall agree to any Change Order that modifies the basis of design of the pre-treatment systems supplied by UOP pursuant to the Phase 2 Pretreatment Contract that would require subsequent changes to the basis of design for the equipment delivered under any of the Phase 2 LTS Purchase Order or the PIS 2022 Purchase Order unless the Borrower delivers together with such Change Order a written confirmation from BHES that such modification does not affect any performance guarantee (including any minimum performance guarantee or unconditional performance obligation under either the Phase 2 LTS Purchase Order or the PIS 2022 Purchase Order), in which event such Change Order shall be permitted (subject to Section 9.1 (Change Orders)).

 

  10.

REPORTING BY THE BORROWER

The Borrower shall be bound by the following reporting obligations:

 

  10.1

Accounting, Financial and Other Information

The Borrower shall:

 

  (a)

furnish to the Intercreditor Agent:

 

  (i)

within 60 days following the end of the first three fiscal quarters of each fiscal year, beginning with the fiscal quarter ending March 31, 2023, (x) the unaudited consolidating balance sheet of the Obligors as of the end of such quarter, (y) the unaudited consolidating statement of operations of the Obligors for such quarter and the portion of the fiscal year through the end of such quarter, and (z) the unaudited statement of cash flows of the Obligors for the portion of the fiscal year through the end of such quarter; and

 

-81-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

within 120 days after the end of each fiscal year beginning with the fiscal year ending December 31, 2022, the Obligors’ consolidating annual financial statements, audited by the Independent Accountants, accompanied by an audit opinion of such Independent Accountants to the effect that such financial statements fairly present, in all material respects, the financial position and results of operations and cash flows of the Obligors in accordance with GAAP (which opinion shall not be subject to any “going concern” qualification); and

 

  (iii)

(A) concurrently with the delivery of the financial statements pursuant to clause (a)(i) above for each fiscal quarter beginning with the fiscal quarter ending March 31, 2023, (x) in comparative form, the unaudited consolidating balance sheet of the Obligors as of the end of the prior fiscal year, (y) in comparative form, the unaudited consolidating statement of operations of the Obligors for such quarter and the portion of the fiscal year through the end of such quarter for the corresponding period in the previous year and (z) in comparative form, the unaudited statement of cash flows of the Obligors for the portion of the fiscal year through the end of such quarter for the corresponding period in the previous year and (B) concurrently with the delivery of the financial statements pursuant to clause (a)(ii) above for each fiscal year beginning with the fiscal year ending December 31, 2023, comparative form financial statements with respect to the prior fiscal year.

 

  (b)

concurrently with the delivery of the financial statements pursuant to clause (a) above, furnish:

 

  (i)

a certificate executed by an Authorized Officer of each of the Obligors certifying that such financial statements fairly present in all material respects the financial condition and results of operations of the Obligors on the dates and for the periods indicated in accordance with GAAP, subject, in the case of a quarterly financial statement, to the absence of notes and normal year-end audit adjustments;

 

  (ii)

a certificate executed by an Authorized Officer of the Borrower certifying that no Unmatured Loan Facility Event of Default or Loan Facility Event of Default exists as of the date of such certificate or, if any Unmatured Loan Facility Event of Default or Loan Facility Event of Default exists, specifying the nature and extent thereof; and

 

  (iii)

a written summary of Gas hedges entered into by any Obligor, detailing aggregate outstanding contract volumes, price ranges of such Gas hedges and the associated value at risk with respect to such Gas hedges for the Development as of the end of each quarter.

 

-82-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

Upon a reasonable request from any Facility Agent, furnish (i) any change in the information provided in the Beneficial Ownership Certification that would result in a change to the list of beneficial owners identified in sections (i) or (ii) of such certification and (ii) any documents that are required in order for each Facility Lender to carry out all necessary “know your customer” or similar requirements, including those reasonably required to ensure compliance with anti-money laundering procedures (including the USA Patriot Act) in its relevant jurisdiction, in each case under this clause (ii) to the extent not otherwise delivered to the relevant Finance Party at or prior to the Upsize Closing Date or subsequently delivered.

 

  10.2

Quarterly Historical DSCR Certificate

No later than 15 Business Days following the last day of each fiscal quarter following the First Repayment Date after the Project Phase 1 Completion Date, the Borrower shall calculate and deliver to the Collateral Agent its calculation of the Historical DSCR for the most recent 12-month period.

 

  10.3

Notices

The Borrower shall provide prompt written notice to the Intercreditor Agent and each Facility Agent upon any Obligor having Knowledge of any:

 

  (a)

Unmatured Loan Facility Event of Default or Loan Facility Event of Default and any action being taken or proposed to be taken with respect thereto;

 

  (b)

damage, loss or destruction of all or a material portion of the Project Facilities or an Event of Taking in excess of $125 million in value or any series of such events or circumstances during any 12-month period in excess of $375 million in value in the aggregate, or the initiation of any insurance claim proceedings with respect to any such event;

 

  (c)

claim, Environmental Claim, suit, arbitration, litigation or similar proceeding pending or threatened in writing (i) with respect to or against the Development or the Collateral Parties (A) in which the amount involved is in excess of $375 million; (B) that could reasonably be excepted to have a Material Adverse Effect; or (C) involving injunctive or declaratory relief; or (ii) involving any other party to any of the Material Project Agreements, in each case, which could reasonably be expected to have a Material Adverse Effect or result in a Loan Facility Event of Default, and, in each case, copies or summaries thereof and a description of any action being taken or proposed to be taken with respect thereto;

 

-83-

Plaquemines – Amended & Restated Common Terms Agreement


  (d)

dispute, litigation, investigation or proceeding between any Governmental Authority and a Collateral Party involving the Development in which the amount involved is in excess of $375 million or that could reasonably be expected to have a Material Adverse Effect, in each case, including a reasonable summary thereof;

 

  (e)

force majeure event in respect of the Development reasonably expected to exceed 30 consecutive days, including its expected duration and any action being taken or proposed to be taken with respect thereto;

 

  (f)

cessation of activities by any of the Construction Contractors, the Manager or the Operator or the Pipeline Operator, as applicable, related to the Development that is not otherwise reflected in the Construction Budget and Schedule and could reasonably be expected to exceed 60 consecutive days;

 

  (g)

unless previously notified pursuant to another provision in the Finance Documents, event, occurrence or circumstance that could reasonably be expected to cause:

 

  (i)

an increase of more than an aggregate of $200 million in Project Costs which has not been previously notified pursuant to Article 9 (Material Construction Contracts); or

 

  (ii)

Operation and Maintenance Expenses to exceed the amount budgeted therefor by 10% or more in the aggregate per annum or 20% per line item per annum, calculated as set forth in Section 12.3 (Project Construction; Maintenance of Properties);

 

  (h)

an ERISA Event or any other event or circumstance that could reasonably be expected to result in material liability to any Collateral Party under ERISA or under the Code with respect to any Plan or Multiemployer Plan;

 

  (i)

material modifications to any Senior Debt Instrument, together with copies of such modifications;

 

  (j)

material Permit obtained by a Collateral Party or for the benefit of the Development not previously delivered, when available to the Collateral Party, together with a copy of such Permit;

 

  (k)

material written statement or report received by a Collateral Party from Operator or the Pipeline Operator, as applicable, pursuant to the O&M Agreements together with a copy of such statement or report;

 

  (l)

Impairment of any material Permit;

 

-84-

Plaquemines – Amended & Restated Common Terms Agreement


  (m)

notice to be delivered or received pursuant to any Material Project Agreement that is material to the Development, together with a copy thereof;

 

  (n)

prepayment of Senior Debt resulting in a Hedging Excess Amount, which notice shall certify:

 

  (i)

the total amount of such Hedging Excess Amount; and

 

  (ii)

the allocation of the Hedging Excess Amount across the applicable Permitted Hedging Instruments in respect of which the hedged amount is to be reduced;

 

  (o)

execution of material agreements entered into by an Obligor after the Upsize Closing Date, which notices shall be provided at least five Business Days prior to the execution of any such agreement or earlier if expressly specified herein;

 

  (p)

when available, copies (with commercially sensitive information redacted) of material agreements entered into by an Obligor after the Upsize Closing Date (not already delivered to the Intercreditor Agent pursuant to another provision of the Finance Documents);

 

  (q)

event (other than any event specified above) that could reasonably be expected to have a Material Adverse Effect;

 

  (r)

on an annual basis, a copy of the Composite ADP (as such term is defined in each Initial LNG SPA) provided by the Borrower under the Initial LNG SPAs; and

 

  (s)

any failure by the Borrower to deliver at least 50% of the LNG required to be made available by the Borrower in accordance with the applicable delivery schedule under any Qualifying LNG SPA in any month, and any action taken or proposed to be taken in connection therewith.

 

  10.4

Construction Reports

 

  (a)

Prior to the Project Phase 2 Completion Date, as soon as available and in any event:

 

  (i)

within 30 days following the end of each month (or if such date is not a Business Day, the following Business Day), the Borrower shall deliver to the Independent Engineer:

 

-85-

Plaquemines – Amended & Restated Common Terms Agreement


  (A)

each of the construction reports provided to the Obligors under the Material Construction Contracts and Site Work Contracts during the prior month;

 

  (B)

a consolidated progress curve showing the overall planned and actual progress for the Project based on the agreed weightings for each component part of the Project (such progress curve to be broken out to show progress in respect of each of (x) the Phase 1 Project Facilities and (y) the Phase 2 LNG Facility);

 

  (C)

a summary table showing the Construction Budget and Schedule as of the Upsize Closing Date, cash spend to date under each contract, and the then-projected final cost of each Material Construction Contract and Site Works Contract and the overall Project, the forecast of which shall be updated no less frequently than semi-annually with qualitative cost trend reports no less frequently than three times a year;

 

  (D)

to the extent not already included in the reports described in clauses (a)(i)(A) through (C) above, a listing of reportable environmental, health and safety incidents, any material unplanned related impacts, events, accidents or issues, and any material non-compliance with Environmental Laws during the report period, and any amendments, modifications or updates to the Environmental and Social Management Plan and Equator Principles Action Plan that occurred during the report period; and

 

  (ii)

by the fifteenth Business Day of the month following the month in sub-clause (i) above, a monthly construction report prepared by the Independent Engineer regarding the Project Facilities; provided that the failure to provide such construction report pursuant to this sub- clause (ii) by the fifteenth Business Day following the end of each such month (other than as a result of an act or omission by the Borrower or its Affiliates) shall not constitute an Unmatured Loan Facility Event of Default or a Loan Facility Event of Default.

 

  (b)

The monthly construction report prepared by the Independent Engineer shall set forth the following in reasonable detail:

 

  (i)

estimated dates on which the LPS1 Substantial Completion Date, the LPS2 Substantial Completion Date, the LPS3 Substantial Completion Date (each as defined in the Phase 1 EPC Contract), the LPS5 Substantial Completion Date (as defined in the Phase 2 EPC Contract), each Commercial Operation Date, the Project Phase 1 Completion Date and the Project Phase 2 Completion Date shall be achieved;

 

-86-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

the Borrower’s estimate of overall completion at the end of the subject month together with the Independent Engineer’s observations on same;

 

  (iii)

then-current estimate of anticipated Project Costs through the Project Phase 2 Completion Date as compared to the then current Construction Budget and Schedule and in the event of a material variance, the reasons therefor;

 

  (iv)

any event or circumstance the occurrence of which could reasonably be expected to:

 

  (A)

increase the total Project Costs materially above those set forth in the then current Construction Budget and Schedule;

 

  (B)

delay the Project Phase 1 Completion Date beyond the Phase 1 LNG Facility Date Certain or the Project Phase 2 Completion Date beyond the Phase 2 LNG Facility Date Certain (as reasonably anticipated by the Borrower as of such time); or

 

  (C)

have a Material Adverse Effect;

 

  (v)

if the Project Phase 1 Completion Date is not anticipated to occur on or before the Phase 1 LNG Facility Date Certain or the Project Phase 2 Completion Date is not anticipated to occur on or before the Phase 2 LNG Facility Date Certain, the reasons therefor (and a discussion of the schedule recovery plan);

 

  (vi)

the status of construction of the Project Facilities, including progress under each Material Construction Contract and Site Works Contract (and a description of any material defects or deficiencies with respect thereto), and the proposed construction schedule for the following 90 days of the Project Facilities, including a description, as compared with the then current Construction Budget and Schedule, of the status of engineering, procurement, construction, commissioning and testing;

 

  (vii)

the status of construction of the Gator Express Pipeline;

 

-87-

Plaquemines – Amended & Restated Common Terms Agreement


  (viii)

the status of construction of the interconnection facilities being constructed in accordance with each of the Gas Transportation Agreements;

 

  (ix)

a copy of any filing made by an Obligor with:

 

  (A)

FERC with respect to the Development; or

 

  (B)

the DOE with respect to the export of LNG from the Project Facilities,

(except in each case such filings as are routine or ministerial in nature), which copy may be provided by means of a link to the website where such filing is posted;

 

  (x)

a copy of any filing made by any Person other than an Obligor with:

 

  (A)

FERC with respect to the Development in any proceeding in which an Obligor is the captioned party or respondent; or

 

  (B)

the DOE with respect to the export of LNG from the Project Facilities in any proceeding in which an Obligor is the captioned party or respondent,

(except in each case such filings as are routine or ministerial in nature), which copy may be provided by means of a link to the website where such filing is posted;

 

  (xi)

updates to Schedule F (Material Permits) hereto reflecting the status of any material Permits necessary for the Development, including the dates of applications submitted or to be submitted and the anticipated dates of actions by Governmental Authorities with respect to such Permits; and

 

  (xii)

a discussion of reportable environmental, health and safety incidents, any material unplanned related impacts, events, accidents or issues, and any material non-compliance with Environmental Laws during the report period, and any amendments, modifications or updates to the Environmental and Social Management Plan and Equator Principles Action Plan that occurred during the report period.

 

-88-

Plaquemines – Amended & Restated Common Terms Agreement


  10.5

Operating Budget

 

  (a)

No less than 30 days prior to the earlier of (x) the Commercial Operation Date under any of the Required LNG SPAs then in effect and (y) LPS1 Substantial Completion, in each case, as reasonably estimated by the Borrower as of the date such report is provided, and no less than 30 days prior to the beginning of each calendar year thereafter, the Obligors shall prepare a proposed operating plan and budget setting forth in reasonable detail the projected requirements for Operation and Maintenance Expenses for the Obligors and the Development for the ensuing calendar year (or, in the case of the initial Operating Budget, the remaining portion thereof) and provide the Independent Engineer and the Intercreditor Agent with a copy of such operating plan and budget (the “Operating Budget”).

 

  (b)

Each Operating Budget shall be prepared in accordance with a form provided to and accepted by the Independent Engineer prior to the earlier of (x) the Commercial Operation Date under any of the Required LNG SPAs then in effect and (y) LPS1 Substantial Completion in its reasonable judgment (with any material changes to such form as may be confirmed to be reasonable by the Independent Engineer).

 

  (c)

Each Operating Budget shall set forth all material assumptions used in the preparation of such Operating Budget and each such Operating Budget shall become effective 30 days following delivery thereof to the Intercreditor Agent unless the Intercreditor Agent, acting reasonably and in consultation with the Independent Engineer, objects in writing (stating its reasons for such objection) to such Operating Budget prior to such 30th day; provided that the Intercreditor Agent shall have neither the right nor the obligation to approve or object to costs for Gas purchase contracts for the Development or any financing-related costs or expenses contained in the Operating Budget. If the Obligors do not have an effective annual Operating Budget before the beginning of any calendar year, until such proposed Operating Budget is effective, the Operating Budget most recently in effect shall continue to apply; provided that (A) any items of the proposed Operating Budget that have not been objected to shall be given effect in substitution of the corresponding items in the Operating Budget most recently in effect, (B) costs for Gas purchase contracts for the Development shall be as provided by the Obligors and (C) all other items shall be increased by the lesser of (x) 2.5% and (y) the increase proposed by the Obligors for such item in such proposed Operating Budget.

 

  (d)

The Obligors shall provide notice to the Independent Engineer and Intercreditor Agent of any material amendments to the Operating Budget that occur during the course of a calendar year. Any such amendment shall become effective 30 days following delivery thereof to the Intercreditor Agent unless the Intercreditor Agent, acting reasonably and in consultation with the Independent Engineer, objects to such amendment prior to such 30th day.

 

-89-

Plaquemines – Amended & Restated Common Terms Agreement


  10.6

Operating Statements and Reports

Within 60 days following the end of each fiscal quarter (other than the last fiscal quarter of any fiscal year) and 90 days following the end of each fiscal year, commencing with the close of the first full fiscal quarter after the earlier of (x) the Commercial Operation Date under any of the Required LNG SPAs then in effect and (y) the date LPS1 Substantial Completion is achieved, the Borrower shall deliver to the Intercreditor Agent and the Independent Engineer quarterly and annual operating statements, respectively, which shall:

 

  (a)

correspond to the expenditure categories and monthly periods of the current annual Operating Budget and show all Cash Flows and all expenditures for Operation and Maintenance Expenses during such quarterly period and for the portion of the Borrower’s fiscal year then ended, and the fiscal year then ended, respectively;

 

  (b)

in the case of the quarterly operating statement, include:

 

  (i)

updated estimates of Operation and Maintenance Expenses for the balance of such fiscal year to which the operating statement relates;

 

  (ii)

a summary of key performance indicators used to monitor the operation of the Project Facilities during such quarterly period and capacity test results if any are performed during such quarterly period;

 

  (iii)

records on efficiency, performance and availability of the Project Facilities during such fiscal quarter;

 

  (iv)

discussion of any material deviation from the requirements set forth in Section 12.3 (Project Construction; Maintenance of Properties), stating in reasonable detail the necessary qualifications to such requirements;

 

  (v)

the cause, duration and projected loss of Cash Flows attributable to each material scheduled and unscheduled interruption in the liquefaction and other services to be provided under the LNG SPAs by the Project Facilities during such fiscal quarter and, with respect to any interruptions caused by a material defect or failure, the cause of and cost to repair such defect or failure;

 

  (vi)

a listing of reportable environmental, health and safety incidents, any material unplanned related impacts, events, accidents or issues, and any material non-compliance with Environmental Laws, and any amendments, modifications or updates to the Environmental and Social Management Plan and Equator Principles Action Plan that occurred during the report period; and

 

-90-

Plaquemines – Amended & Restated Common Terms Agreement


  (vii)

a summary of firm Gas supply arrangements into which the Borrower has entered and listing the pipelines with which firm transportation agreements have been executed and the volumes of capacity associated therewith.

 

  (c)

include a copy of any filing made by an Obligor:

 

  (i)

with FERC with respect to the Development; or

 

  (ii)

with the DOE with respect to the export of LNG from the Project Facilities,

(except in each case such filings as are routine or ministerial in nature), which copy may be provided by means of a link to the website where such filing is posted;

 

  (d)

include a copy of any filing made by any Person other than an Obligor:

 

  (i)

with FERC with respect to the Development in any proceeding in which an Obligor is the captioned party or respondent; or

 

  (ii)

with the DOE with respect to the export of LNG from the Project Facilities in any proceeding in which an Obligor is the captioned party or respondent,

(except in each case such filings as are routine or ministerial in nature), which copy may be provided by means of a link to the website where such filing is posted;

 

  (e)

be accompanied by a statement of sources and uses of funds for the periods covered by it and a discussion of the reason for any material:

 

  (i)

variance from the amount budgeted therefor in the relevant Operating Budget; and

 

  (ii)

variance in the actual costs for the then-current period from the costs incurred during the prior period; and

 

  (f)

be certified as materially complete and correct by an Authorized Officer of the Borrower.

 

-91-

Plaquemines – Amended & Restated Common Terms Agreement


  10.7

Insurance Reporting

 

  (a)

The Borrower shall provide to the Intercreditor Agent:

 

  (i)

evidence of Minimum Insurance set forth on, and subject to the provisions of, the Schedule of Minimum Insurance:

 

  (A)

by the later of (1) the Upsize Closing Date and (2) in respect of any Material Construction Contract, the date of issuance of the “Notice to Proceed” or “FNTP” pursuant to such Material Construction Contract;

 

  (B)

prior to the transfer of care, custody and control in respect of each of LPS1, LPS2, LPS3, LPS4, LPS5 and LPS6 in accordance with the Material Construction Contracts; and

 

  (C)

upon the renewal or replacement of any insurance policy required under the Schedule of Minimum Insurance;

 

  (ii)

notice as soon as reasonably practicable of:

 

  (A)

any failure to pay any premium on Minimum Insurance (and in any case, by the date falling ten days after it is due);

 

  (B)

any actual or reasonably anticipated material reduction in Minimum Insurance coverage (and in any case, within five Business Days after becoming aware of such reduction);

 

  (C)

any failure to maintain Minimum Insurance coverage (including any cancellation, termination or suspension (for any reason) of any Minimum Insurance) (and in any case, within five Business Days after becoming aware of such cancellation, termination or suspension);

 

  (D)

any single loss or event likely to give rise to a property damage or liability claim against an insurer for an amount in excess of $150 million (and in any case, within five Business Days after becoming aware of such loss or event);

 

  (E)

without prejudice to its other obligations under this Section 10.7 (Insurance Reporting), Article 5 (Insurance and Condemnation Proceeds and Performance Liquidated Damages) of the Common Security and Account Agreement or Section 12.28 (Insurance Covenant), any fact, event or circumstance that has caused, or that with the giving of notice or lapse of time would cause, it to be in breach of any

 

-92-

Plaquemines – Amended & Restated Common Terms Agreement


  provision of this Section 10.7 (Insurance Reporting), Article 5 (Insurance and Condemnation Proceeds and Performance Liquidated Damages) of the Common Security and Account Agreement or Section 12.28 (Insurance Covenant) or the requirements of any of the Borrower’s Minimum Insurance policies, and:

 

  (1)

the steps it proposes to take in order to remedy such breach or, if such breach cannot be remedied, to mitigate the risk or liability to which the Project Facilities have been or shall reasonably be expected to be exposed by virtue of the occurrence of such breach; and

 

  (2)

its good faith estimate of the period required to implement, and the cost of, such steps.

 

  (b)

The evidence of Minimum Insurance provided pursuant to Section 10.7(a)(i)(A) (Insurance Reporting) above shall be provided in the form of certificates of insurance, binders or other customary documentation evidencing the existence of all insurance required to be maintained at such time by the Obligors, together with a certificate of the Borrower setting forth the insurance obtained and stating:

 

  (i)

that such insurance required to be maintained at such time by the Obligors as set forth in the Schedule of Minimum Insurance has been obtained and in each case is in full force and effect;

 

  (ii)

that such insurance complies with the requirements of the Schedule of Minimum Insurance and is otherwise in accordance with the Finance Documents in all material respects; and

 

  (iii)

that all premiums then due and payable on all such insurance have been paid.

 

  10.8

Copies of Finance Documents

Promptly following the Upsize Closing and following entry by any Obligor into a new Finance Document, the Borrower shall deliver copies of such newly executed Finance Document to the Collateral Agent, Intercreditor Agent, each Facility Agent and each Facility Lender party to the Finance Documents.

 

-93-

Plaquemines – Amended & Restated Common Terms Agreement


  10.9

Construction Budget and Schedule

If the Construction Budget and Schedule is amended, supplemented or otherwise modified in accordance with the Finance Documents, the Borrower shall (a) to the extent such update was made in reliance on the proviso in Section 9.1(a)(i) (Change Orders), deliver to the Intercreditor Agent such updated Construction Budget and Schedule in connection with delivery of financial statements pursuant to Section 10.1(a) (Accounting, Financial and Other Information) and (b) to the extent such update was not made in reliance on the proviso in Section 9.1(a)(i) (Change Orders), promptly deliver to the Intercreditor Agent such updated Construction Budget and Schedule in connection with any requests for Change Orders pursuant to Section 9.1 (Change Orders) requiring the consent of the Intercreditor Agent, acting in reliance on and in consultation with the Independent Engineer.

 

11.

RESTRICTED PAYMENTS

 

  11.1

Conditions to Restricted Payments

Restricted Payments may be made provided that each of the following, and no other, conditions has been satisfied:

 

  (a)

no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing or could reasonably be expected to occur as a result of such Restricted Payment;

 

  (b)

(i) the Historical DSCR for the most recent 12-month period (calculated excluding any amount contributed during such measurement period under the cure right in Section 12.25 (Historical DSCR)) and (ii) the Fixed Projected DSCR for the 12-month period beginning on the Quarterly Payment Date on or immediately prior to the proposed date of the Restricted Payment are, in each case, at least 1.25:1;

 

  (c)

the Senior Facilities Debt Service Reserve Account is funded (with cash or Acceptable Debt Service Reserve LCs) with the then-applicable Senior Facilities Reserve Amount;

 

  (d)

each of the Project Phase 1 Completion Date and the Project Phase 2 Completion Date has occurred;

 

  (e)

no outstanding LC Loans (as defined in the Credit Facility Agreement) or LC Reimbursement Payments are outstanding as of the date of such Restricted Payment;

 

  (f)

the then-Required LNG SPAs are in full force and effect and no actual LNG SPA Prepayment Event or Unmatured LNG SPA Prepayment Event has occurred and is continuing in respect of which the prepayment and cancellation required by the occurrence of such event in accordance with Section 8.2 (LNG SPA Mandatory Prepayment) has not been made in full;

 

-94-

Plaquemines – Amended & Restated Common Terms Agreement


  (g)

no other Restricted Payment (other than any Restricted Payment permitted under Section 11.2 (Certain Restricted Payments), Section 11.3 (Project Phase 1 Pre-Completion Revenue Restricted Payments) or Section 11.4 (Project Phase 2 Pre-Completion Revenue Restricted Payments)) has been made during the calendar quarter of the proposed Restricted Payment; and

 

  (h)

at least two Business Days prior to the proposed date of such Restricted Payment, the Intercreditor Agent has received a certificate from the Borrower confirming that each of the conditions set forth in this Section 11.1 (Conditions to Restricted Payments) have been satisfied and setting forth the calculation of the Historical DSCR and the Fixed Projected DSCR in clause (b) above.

 

  11.2

Certain Restricted Payments

The following payments may be made at any time in accordance with the terms of this Agreement and the other Finance Documents, without complying with the conditions set forth in Section 11.1 (Conditions to Restricted Payments):

 

  (a)

reimbursements of equity (other than any Equity Contributions) pursuant to Section 3.4(a)(ii) (Mandatory Prepayments – Performance Liquidated Damages);

 

  (b)

reimbursements of equity (other than any Equity Contributions) pursuant to Section 5.2(h) (Insurance and Condemnation Proceeds) of the Common Security and Account Agreement;

 

  (c)

reimbursements of Drawstop Equity Contributions in accordance with Section 4.5(d)(iv) (Deposits and Withdrawals – Construction Account) of the Common Security and Account Agreement, but subject to all conditions precedent set forth in Section 4.3 (Conditions to Each Term Loan Advance) for an Advance in connection with such reimbursement of the Drawstop Equity Contributions have been met or waived and solely to the extent the proceeds of such Drawstop Equity Contributions have been used to pay Project Costs (it being understood and agreed that Equity Contributions shall be required to be applied from the Construction Account (or, prior to the Upsize Closing Date, the Excess Equity Proceeds Account, as applicable) to the payment of Project Costs and not to be subject to reimbursement under this clause (c));

 

  (d)

[reserved]; and

 

-95-

Plaquemines – Amended & Restated Common Terms Agreement


  (e)

so long as (i) the Obligors have satisfied the conditions to the Project Phase 2 Completion Date set forth in Section 14.3 (Conditions to Occurrence of the Project Phase 2 Completion Date), and (ii) on a pro forma basis, after giving effect to any Project Phase 2 Completion Date Distribution, Senior Debt/Equity Ratio shall be no greater than 75:25, the making of the Project Phase 2 Completion Date Distribution, if any, in accordance with Section 4.5(d)(vi) (Deposits and Withdrawals – Construction Account) of the Common Security and Account Agreement and Section 14.4(c) (Project Phase 2 Completion Date Waterfall) hereof.

 

  11.3

Project Phase 1 Pre-Completion Revenue Restricted Payments

Notwithstanding anything to the contrary in Section 11.1 (Conditions to Restricted Payments), Restricted Payments in respect of Pre-Completion Revenues may be made from the Phase 1 Pre-Completion Revenues Account on and prior to the Project Phase 1 Completion Date; provided that, in each case, each of the following, and no other, conditions has been satisfied:

 

  (a)

no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing or could reasonably be expected to occur as a result of such Restricted Payment;

 

  (b)

each of LPS1 Substantial Completion, LPS2 Substantial Completion and LPS3 Substantial Completion has occurred;

 

  (c)

the funds on deposit in the Contingency Reserve Account, and the remaining undrawn amount of the Contingency Reserve Term Loan Commitments are, collectively, equal to or in excess of the Contingency Reserve Amount as described in clause (a) of the definition thereof;

 

  (d)

the Obligors have certified to the Credit Facility Agent, and the Independent Engineer has confirmed, that (A) the Facility Debt Commitments and funds on deposit in the Construction Account, Contingency Reserve Account (excluding the amount equal to the Contingency Reserve Amount as described in clause (a) of the definition thereof), the Phase 1 Pre- Completion Revenues Account, the Phase 2 Pre-Completion Revenues Account, the Disbursement Accounts and the Permitted Finance Costs Reserve Account are sufficient to achieve (x) the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and (y) the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain and (B) the Borrower is reasonably expected to achieve (x) the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and (y) the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain;

 

  (e)

the Fixed Projected DSCR prospectively measured for the 12-month period beginning on the then projected first Quarterly Payment Date in respect of the Term Loans to occur after the Project Phase 1 Completion Date is at least 1.25:1;

 

-96-

Plaquemines – Amended & Restated Common Terms Agreement


  (f)

no outstanding LC Loans (as defined in the Credit Facility Agreement) or LC Reimbursement Payments are outstanding as of the date of such Restricted Payment;

 

  (g)

the then-Required LNG SPAs are in full force and effect and no actual LNG SPA Prepayment Event or Unmatured LNG SPA Prepayment Event has occurred and is continuing in respect of which the prepayment and cancellation required by the occurrence of such event in accordance with Section 8.2 (LNG SPA Mandatory Prepayment) has not been made in full;

 

  (h)

no other Restricted Payment under this Section 11.3 (Project Phase 1 Pre- Completion Revenue Restricted Payments) has been made during the calendar month of the proposed Restricted Payment; and

 

  (i)

at least two Business Days prior to the proposed date of such Restricted Payment, the Intercreditor Agent has received a certificate from the Borrower confirming that each of the conditions set forth in this Section 11.3 (Project Phase 1 Pre-Completion Revenue Restricted Payments) have been satisfied and setting forth the calculation of the Fixed Projected DSCR in clause (e) above.

 

  11.4

Project Phase 2 Pre-Completion Revenue Restricted Payments

Notwithstanding anything to the contrary in Section 11.1 (Conditions to Restricted Payments), Restricted Payments in respect of Pre-Completion Revenues may be made from the Phase 2 Pre-Completion Revenues Account on and prior to the Project Phase 2 Completion Date; provided that, in each case, each of the following, and no other, conditions has been satisfied:

 

  (a)

no Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing or could reasonably be expected to occur as a result of such Restricted Payment;

 

  (b)

each of LPS1 Substantial Completion, LPS2 Substantial Completion, LPS3 Substantial Completion and LPS5 Substantial Completion has occurred;

 

  (c)

the funds on deposit in the Contingency Reserve Account, and the remaining undrawn amount of the Contingency Reserve Term Loan Commitments are, collectively, equal to or in excess of the Contingency Reserve Amount (including, after the Project Phase 1 Completion Date, as reduced after the Project Phase 1 Completion Date);

 

-97-

Plaquemines – Amended & Restated Common Terms Agreement


  (d)

the Obligors have certified to the Credit Facility Agent, and the Independent Engineer has confirmed, that:

 

  (i)

(A) the Facility Debt Commitments, and funds on deposit in the Construction Account, Contingency Reserve Account (excluding the amount equal to the Contingency Reserve Amount), the Phase 1 Pre-Completion Revenues Account, the Phase 2 Pre-Completion Revenues Account, the Disbursement Accounts and the Permitted Finance Costs Reserve Account are sufficient to (x) achieve (I) if the Project Phase 1 Completion Date has not yet occurred, the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and (II) the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain and (y) after the Project Phase 1 Completion Date, pay any Phase 1 Reserve Amounts; and

 

  (ii)

the Borrower is reasonably expected to achieve (x) if the Project Phase 1 Completion Date has not yet occurred, the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and (y) the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain;

 

  (e)

(i) if the Project Phase 1 Completion Date has not yet occurred, the Fixed Projected DSCR prospectively measured for the 12-month period beginning on the then projected first Quarterly Payment Date in respect of the Term Loans to occur after the Project Phase 1 Completion Date is at least 1.25:1 or (ii) if the Project Phase 1 Completion Date has occurred, the most recent 12 month Historical DSCR is at least 1.25:1.00;

 

  (f)

the Fixed Projected DSCR prospectively measured for the 12-month period beginning on the then projected first Quarterly Payment Date in respect of the Term Loans to occur after the Project Phase 2 Completion Date is at least 1.25:1;

 

  (g)

no outstanding LC Loans (as defined in the Credit Facility Agreement) or LC Reimbursement Payments are outstanding as of the date of such Restricted Payment;

 

  (h)

the then-Required LNG SPAs are in full force and effect and no actual LNG SPA Prepayment Event or Unmatured LNG SPA Prepayment Event has occurred and is continuing in respect of which the prepayment and cancellation required by the occurrence of such event in accordance with Section 8.2 (LNG SPA Mandatory Prepayment) has not been made in full;

 

-98-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

no other Restricted Payment under this Section 11.4 (Project Phase 2 Pre- Completion Revenue Restricted Payments) has been made during the calendar month of the proposed Restricted Payment; and

 

  (j)

at least two Business Days prior to the proposed date of such Restricted Payment, the Intercreditor Agent has received a certificate from the Borrower confirming that each of the conditions set forth in this Section 11.4 (Project Phase 2 Pre-Completion Revenue Restricted Payments) have been satisfied and setting forth the calculation of the Fixed Projected DSCR or the Historical DSCR in clause (e) above and the Fixed Projected DSCR in clause (f) above.

 

12.

OBLIGOR COVENANTS

Each Obligor shall comply at all times with the following covenants:

 

  12.1

Use of Proceeds

The Obligors shall use the proceeds of (a) the Upsized Senior Debt as specified in the Credit Facility Agreement and (b) any other Senior Debt in accordance with the Facility Agreement applicable thereto.

 

  12.2

Maintenance of Existence, Franchises, Etc.

 

  (a)

Each Obligor shall maintain its legal existence as a limited liability company;

 

  (b)

no Obligor shall take any action to amend or modify its Constitutional Documents in a manner that is in any material respect adverse to the interests of the Facility Lenders or such Obligor’s ability to comply with the Finance Documents; and

 

  (c)

 

  (i)

each Obligor shall promptly provide copies of any amendments to its Constitutional Documents to the Intercreditor Agent;

 

  (ii)

each Obligor shall maintain and renew all of the powers, licenses, rights, privileges and franchises necessary for the Development and in the normal conduct of its business as conducted or proposed to be conducted, except where the failure to do so could not reasonably be expected to have a Material Adverse Effect;

 

  (iii)

no Obligor shall change, alter or modify its legal business name, jurisdiction of organization or type of organization, in each case without providing the Intercreditor Agent with at least 30 days’ prior notice and without having satisfied its obligations under Section 12.31 (Further Assurances); and

 

-99-

Plaquemines – Amended & Restated Common Terms Agreement


  (iv)

no Obligor shall cease to be for US federal income tax purposes the type of entity specified in Section 5.2(w) (Tax Status).

 

  12.3

Project Construction; Maintenance of Properties

 

  (a)

The Obligors shall construct and complete, operate and maintain the Project Facilities, and cause the Project Facilities to be constructed, operated and maintained, as applicable:

 

  (i)

consistent in all material respects with Prudent Industry Practice, the Material Construction Contracts, the Construction Budget and Schedule, the Operating Manuals, applicable Government Rules, and the other Transaction Documents, and in accordance with the requirements for maintaining the effectiveness of the material warranties of the Construction Contractors; and

 

  (ii)

following the Project Phase 1 Completion Date, within the then- effective Operating Budget; provided that:

 

  (A)

the Obligors may exceed in the aggregate for all operating budget categories in any Operating Budget by 20% or less per line item of the amount therefor and 10% or less of the aggregate budgeted amount therefor, in each case on an annual basis, but excluding, for purposes of calculating the foregoing allowable increases, amounts in the then-effective Operating Budget for Gas purchases; and

 

  (B)

the Obligors may exceed the Operating Budget and any category thereof:

 

  (1)

with respect to payments under Gas purchase contracts for the Development;

 

  (2)

as required by law or regulation, Industry Standards, Prudent Industry Practice or for compliance with any Permit applicable to the Obligors or the Development (or to cure or remove the effect of any termination, suspension, or impairment of any Permit), as certified by the Borrower (with the reasonable concurrence of the Independent Engineer); or

 

-100-

Plaquemines – Amended & Restated Common Terms Agreement


  (3)

to the extent required to respond to an emergency or accident, the failure to respond to which could reasonably be expected to create a risk of personal injury or significant physical damage to the Project Facilities or material threat to the environment, in which case:

 

  (I)

if the Obligors reasonably determine that there is sufficient time to do so prior to responding to any such emergency or accident, the Borrower shall substantiate the expenses expected to be incurred by the Obligors in connection with such emergency or accident to the reasonable satisfaction of the Intercreditor Agent; or

 

  (II)

if the Obligors reasonably determine that there is not sufficient time to take the actions described in sub-clause (3) above prior to responding to any such emergency or accident, promptly following such emergency or accident, the Borrower shall describe in writing to the Intercreditor Agent the steps that were taken by the Obligors in respect of such emergency or accident and the expenses incurred by the Obligors in connection therewith, all in reasonable detail.

 

  12.4

Books and Records; Inspection Rights

 

  (a)

The Obligors shall make available to the Intercreditor Agent, on request, copies or extracts of books and records of the Obligors:

 

  (i)

when a Loan Facility Event of Default has occurred and is Continuing; and

 

  (ii)

otherwise up to two times (which shall be reasonably spaced within the applicable period) per calendar year during normal business hours upon 30 days’ advance notice,

subject to the confidentiality arrangements pursuant to Section 12.6 (Confidentiality) of the Common Security and Account Agreement and Section 23.7 (Confidentiality) below.

 

-101-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

The Obligors shall not, without the prior consent of the Intercreditor Agent (not to be unreasonably withheld, conditioned or delayed), change the end date of their fiscal years.

 

  (c)

The Obligors shall keep proper books and records in accordance with GAAP in all material respects.

 

  12.5

Material Project Agreements

 

  (a)

Each Obligor shall maintain in effect all Material Project Agreements (other than Real Property Documents) that have been entered into and to which it is a party except:

 

  (i)

to the extent a Material Project Agreement is permitted to expire, be terminated or replaced under the Finance Documents or expires or is replaced in accordance with its terms; and

 

  (ii)

to the extent provided under Section 8.1 (LNG SPA Maintenance) and Section 8.2 (LNG SPA Mandatory Prepayment) in relation to LNG SPAs.

 

  (b)

Each Obligor shall comply with its material contractual obligations, and, subject to Section 12.5(e) (Material Project Agreements) below, enforce against Material Project Counterparties its material rights and their material covenants and obligations, under the Material Project Agreements (other than Real Property Documents) then in effect to which it is a party.

 

  (c)

No Obligor shall agree to any amendment or modification of, or waiver relating to, any Material Project Agreement (other than Real Property Documents) to which it is a party that could reasonably be expected to have a Material Adverse Effect or would materially breach the terms of the Finance Documents; provided that amendments or modifications to LNG SPAs as permitted under Section 8.3 (Amendment of LNG SPAs) shall in any case be permitted; provided further that Change Orders as permitted under Section 9.1 (Change Orders) shall in any case be permitted.

 

  (d)

Other than with respect to Real Property Documents, no Obligor shall:

 

  (i)

assign or transfer any interest under any Material Project Agreement without the prior written consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties (except for assignments and transfers contemplated in connection with the Common Security and Account Agreement and other Security Documents);

 

-102-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

consent to any counterparty assigning or transferring any interest under any Material Project Agreement, if such Obligor has consent rights under such Material Project Agreement, without the prior written consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties (not to be unreasonably withheld, conditioned or delayed), except:

 

  (A)

if such assignment or transfer could not reasonably be expected to have a Material Adverse Effect; or

 

  (B)

for assignments and transfers permitted or contemplated in the Common Security and Account Agreement, Direct Agreements or other Security Documents; or

 

  (iii)

permit any Material Project Counterparty to substitute, diminish or otherwise replace any performance security, letter of credit or guarantee supporting such Material Project Counterparty’s obligations thereunder (including, for the avoidance of doubt, any replacement of any Parent Guarantee), except to the extent that such Material Project Counterparty is permitted to do so without the consent of the Borrower or Guarantor, as applicable, under the terms of such Material Project Agreement.

 

  (e)

No Obligor shall initiate or settle arbitration or disputes if the amount in controversy in such arbitration, dispute or settlement is in excess of (x) $30 million in the case of a Real Property Document and (y) $30 million in the case of any other Material Project Agreement.

 

  (f)

The applicable Obligor promptly shall provide the Intercreditor Agent with copies or ensure that copies are provided (with any commercially sensitive material redacted) of any material amendments to, or material waivers relating to, the Material Project Agreements that are permitted under the Finance Documents or that have otherwise been entered into with the consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties (not to be unreasonably withheld, conditioned or delayed).

 

  (g)

The Obligors shall not enter into any new Material Project Agreement or any Subsequent Material Project Agreements (other than Real Property Documents) without the prior written consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties (not to be unreasonably withheld, conditioned or delayed); provided that:

 

-103-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

the Obligors may enter into a Replacement Material Contract without the prior written consent of the Intercreditor Agent or any Facility Lender, if:

 

  (A)

in the case of a termination of any Material Project Agreement (other than an LNG SPA), the Obligors (A) shall have entered into a Replacement Material Contract within 60 days (as such period may be extended an additional 30 days provided the Obligors are proceeding with diligence to replace such terminated Material Project Agreement) after such termination and (B) shall have caused such Replacement Material Contract to become subject to the Liens granted under the Security Documents; or

 

  (B)

in the case of any termination of an LNG SPA, the Borrower (A) shall have entered into a Replacement Material Contract within 90 days (as such period may be extended an additional 90 days provided the Obligors are proceeding with diligence to replace such terminated Material Project Agreement) after the date of such termination and (B) shall have caused such Replacement Material Contract to become subject to the Liens granted under the Security Documents to the same extent as the LNG SPA that was terminated, and in each case, the termination of such LNG SPA could not reasonably be expected to result in a Material Adverse Effect;

 

  (ii)

except for gas supply contracts that constitute Material Project Agreements, the Obligors may enter into new gas supply contracts (copies of which shall be delivered to the Intercreditor Agent) without the prior written consent of the Intercreditor Agent in accordance with Section 12.27(a) (Gas Transportation Arrangements; Gas Purchase Arrangements); and

 

  (iii)

the Borrower may enter into new LNG SPAs in accordance with Section 12.5(k) (Material Project Agreements).

 

  (h)

In connection with any new Material Project Agreement and any Subsequent Material Project Agreement (other than Real Property Documents), the applicable Obligor shall deliver to the Intercreditor Agent, within 30 days following execution of such new Material Project Agreement or any Subsequent Material Project Agreement (with a form of such document to be delivered prior to execution of such new Material Project Agreement or any Subsequent Material Project Agreement):

 

-104-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

each Security Document, if any, necessary to grant the Collateral Agent a first priority perfected Lien in such new Material Project Agreement or such Subsequent Material Project Agreement (subject only to Permitted Liens);

 

  (ii)

evidence of the authorization of the applicable Obligor to execute, deliver and perform such new Material Project Agreement or such Subsequent Material Project Agreement;

 

  (iii)

a certificate of the Borrower certifying that all Permits necessary for the execution, delivery and performance of such new Material Project Agreement or such Subsequent Material Project Agreement have been duly obtained, were validly issued and are in full force and effect;

 

  (iv)

an opinion of counsel to the applicable Obligor and, if a Direct Agreement is required to be obtained from such counterparty pursuant to Section 3.4 (Direct Agreements) of the Common Security and Account Agreement, other than with respect to any Subsequent Material Project Agreements specified in clause (b) of the definition thereof, applying the effort standard set forth in Section 3.4 (Direct Agreements) of the Common Security and Account Agreement to obtaining such opinion as is applicable to obtaining the related Direct Agreement, an opinion of counsel to the counterparty to such new Material Project Agreement or such Subsequent Material Project Agreement; and

 

  (v)

a Direct Agreement in respect of such new Material Project Agreement or such Subsequent Material Project Agreement, but only to the extent such Direct Agreement is required pursuant to Section 3.4 (Direct Agreements) of the Common Security and Account Agreement for an equivalent Material Project Agreement.

 

  (i)

Each Obligor shall maintain, preserve and protect, or make contractual or other provisions to cause to be maintained, preserved and protected, all of the real property interests evidenced by the Real Property Documents except (x) to the extent such Real Property Document is permitted to expire, be terminated or replaced under the Finance Documents or expires or terminates pursuant to its terms and is replaced with substantially equivalent real property interests to the extent necessary for the Development at such time or (y) where failure to do so could not reasonably be expected to have a Material Adverse Effect.

 

  (j)

The prior written consent of the Intercreditor Agent (acting on the instruction of the Requisite Intercreditor Parties (not to be unreasonably withheld, conditioned or delayed)) shall be required in connection with the execution by an Obligor of a document evidencing a real property interest if:

 

-105-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

such real property interest replaces (or is substituted for) a real property interest in a then-existing Real Property Document and such replaced real property interest is necessary at such time for the Development; or

 

  (ii)

if such real property interest does not replace (or is not substituted for) a real property interest in a then-existing Real Property Document, such real property interest:

 

  (A)

is, at such time, necessary for the Development;

 

  (B)

is required to be included in a mortgage pursuant to requirements of Section 3.2(f)(ii) (Security Interests to be Granted by the Obligors – Real Property) of the Common Security and Account Agreement; and

 

  (C)

is evidenced by a Real Property Document which by its terms imposes upon an Obligor obligations or liabilities with an aggregate value in excess of $100 million over its term and is for a term of greater than seven years;

provided, in the case of each of clauses (i) and (ii) above, that no such consent shall be required if the applicable real property interest is being acquired in order to comply with (x) the requirements of any Permit or applicable Government Rules, (y) obligations of any Obligor pursuant to a Material Project Agreement or (z) Prudent Industry Practice pertaining to safety or security measures.

 

  (k)

The Borrower shall not enter into any LNG SPA or any shipping arrangements relating to DPU LNG SPAs, in each case, except as permitted by Section 8.1(a) (LNG SPA Maintenance), Section 8.4 (Sale of Supplemental Quantity), Section 8.5 (Sale of Pre-Completion Quantities) Section 12.5(g)(i)(B) (Material Project Agreements), and Section 12.5(l) (Material Project Agreements).

 

  (l)

The Borrower shall not permit DPU LNG SPAs, in the aggregate, to exceed 1.2 MTPA (the “DPU LNG SPA Quantity Restrictions”).

 

  (m)

Notwithstanding anything to the contrary in this Agreement, the Borrower shall be permitted to enter into contracts in accordance with Section 7.2 (Expansion Contracts).

 

-106-

Plaquemines – Amended & Restated Common Terms Agreement


  12.6

Compliance with Law

 

  (a)

The Obligors shall comply in all material respects with all material applicable Government Rules (excluding tax laws as to which Section 12.13 (Taxes) is applicable and Environmental Laws as to which Section 12.7 (Environmental Compliance) is applicable).

 

  (b)

No Obligor shall Knowingly engage in any activity that violates any Anti- Terrorism and Money Laundering Law or OFAC Law to the extent applicable to such entity.

 

  (c)

The Obligors will not, and will require that their respective Affiliates, directors and officers shall not, directly or, to the Obligors’ Knowledge, indirectly, use the proceeds of the Loans, or lend, contribute or otherwise make available such proceeds to any Subsidiary, joint venture partner or other Person:

 

  (i)

in furtherance of an offer, payment, promise to pay or authorization of the payment or giving of money or anything else of value, to any Person in violation of any Anti-Terrorism and Money Laundering Laws, Applicable Anti-Corruption Laws or Sanctions;

 

  (ii)

to fund any activities or business of or with any Sanctioned Person, or in any country, territory, or region, that, at the time of such funding, is, or whose government is, the target of Sanctions administered OFAC or by the US Department of State, the European Union or His Majesty’s Treasury (as of the date of this Agreement, Cuba, Iran, North Korea, Syria, the Crimea region of Ukraine, the so-called Donetsk People’s Republic and the so-called Luhansk People’s Republic, and the non-government controlled areas of Ukraine in the oblasts of Zaporizhzhia and Kherson); or

 

  (iii)

in any other manner that would result in a violation of any Anti- Terrorism and Money Laundering Laws, Applicable Anti- Corruption Laws or Sanctions administered by the United States, including by OFAC or by the US Department of State, the European Union, any EU Member State or His Majesty’s Treasury of the United Kingdom, by any Person (including any Person participating in the Loans, whether as Facility Lender, Intercreditor Agent, or otherwise).

 

  (d)

The Borrower agrees that if it becomes aware of or receives any notice that an Obligor, any Affiliate or any Person holding a legal or beneficial interest therein (whether directly or indirectly) is a Sanctioned Person (a “Sanctions Violation”), the Borrower shall promptly:

 

-107-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

give notice to the Intercreditor Agent of such Sanctions Violation; and

 

  (ii)

comply with all applicable laws governing such Sanctions with respect to such Sanctions Violation (regardless of whether the Sanctioned Person is located within the jurisdiction of the United States).

 

  (e)

The Borrower authorizes and consents to the Intercreditor Agent and each Senior Creditor Group Representative taking any and all steps such parties deem necessary to comply with all applicable laws governing such Sanctions with respect to any such Sanctions Violation, including the “freezing” or “blocking” of assets and reporting such action to the applicable regulatory authorities.

 

12.7

Environmental Compliance

The Obligors shall:

 

  (a)

comply in all material respects with applicable Environmental Laws;

 

  (b)

provide to the Intercreditor Agent (with a copy to each Facility Agent) (i) as promptly as practicable following the Initial Closing Date, the initial version(s) of an “Environmental and Social Management Plan” and (if applicable) “Equator Principles Action Plan” with respect to the Borrower’s material compliance with Equator Principles, in each case, developed with the reasonable cooperation of the Independent Engineer, and thereafter (but no more frequently than semi-annually), any updates thereto and (ii) on an annual basis for each fiscal year following the Initial Closing Date, a certification that the Borrower is in compliance in all material respects with any requirements of the Environmental and Social Management Plan and Equator Principles (including reporting requirements with respect to greenhouse gas emissions) to the extent applicable to the Borrower;

 

  (c)

not Release, and use commercially reasonable efforts not to permit the Release by its Construction Contractors or agents of, any Hazardous Materials at, on, under or from the Project Facilities or any Real Estate on which any Project Facilities are situated in quantities or concentrations that could reasonably be expected to result in a Material Adverse Effect; and

 

  (d)

following the receipt of any material Environmental Claim or notice of any material noncompliance with any Environmental Law, prepare a report detailing the facts underlying the claim or noncompliance and an action plan for responding to the claim or the noncompliance consistent with Prudent

 

-108-

Plaquemines – Amended & Restated Common Terms Agreement


Industry Practice and provide such report and plan to the Independent Engineer and the Intercreditor Agent.

 

12.8

Permits

 

  (a)

The Obligors shall obtain by the time they are required, maintain in full force and effect, and comply in all material respects with all applicable material Permits set forth on Schedule F (Material Permits) (excluding Export Authorizations, as to which Section 12.9 (Export Authorizations) is applicable, and the FERC Order, as to which Section 12.10 (FERC Order) is applicable).

 

  (b)

The Obligors shall not amend or modify a material Permit set forth on Schedule F (Material Permits) or any conditions thereof (excluding Export Authorizations, as to which Section 12.9 (Export Authorizations) is applicable, and the FERC Order, as to which Section 12.10 (FERC Order) is applicable); provided that the Obligors may amend or modify such Permits and any conditions thereof so long as such amendment or modification could not reasonably be expected to have a Material Adverse Effect or result in an Impairment of such Permit and such amendment or modification is not materially more restrictive or onerous on the applicable Obligor.

 

12.9

Export Authorizations

 

  (a)

The Obligors shall use all reasonable efforts to maintain in full force and effect and will comply in all material respects with both the FTA Authorization and the Non-FTA Authorization.

 

  (b)

If an Export Authorization is Impaired, the Obligors shall use all reasonable efforts to promptly and diligently take reasonable steps to reverse such Impairment.

 

12.10

FERC Order

 

  (a)

From and after the Initial Closing Date, the Obligors shall maintain in full force and effect and comply in all material respects with the FERC Order.

 

-109-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

The Obligors shall not propose to amend or modify the FERC Order or any conditions of the FERC Order; provided that the Obligors may propose to amend or modify the FERC Order and any conditions thereof so long as such amendment or modification could not reasonably be expected to have a Material Adverse Effect and such amendment or modification is not materially more restrictive or onerous on the applicable Obligor.

 

12.11

Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages

The Intercreditor Agent, each Senior Creditor Group Representative and the Independent Engineer shall have the right to witness and verify each Performance Test, the Phase 1 Lenders’ Reliability Test and the Lenders’ Reliability Test, and no Obligor shall:

 

  (a)

permit a Performance Test, the Phase 1 Lenders’ Reliability Test or the Lenders’ Reliability Test to be performed without giving the Intercreditor Agent at least three Business Days’ prior notice thereof (or such shorter period agreed by the Independent Engineer); or

 

  (b)

agree in a dispute with any Construction Contractor with respect to the amount of any Performance Liquidated Damages or Delay Liquidated Damages, or to a settlement with respect to such damages, in excess of $30 million without prior approval of the Intercreditor Agent, acting reasonably and in consultation with the Independent Engineer.

 

12.12

Inspection Rights

The Obligors shall grant access to the Site to the Consultants and designated representatives of Facility Lenders at the times and in the manner described in Section 13.3 (Access).

 

12.13

Taxes

Each Obligor shall pay or cause to be paid all material Taxes (if any) imposed on or in respect of such Obligor or its property by any Governmental Authority, when due, giving effect to any applicable extensions, unless these are being contested in good faith and by appropriate proceedings and an appropriate reserve has been established in respect thereof in accordance with GAAP. Each Obligor shall notify the Intercreditor Agent of any material dispute with the relevant tax authorities. Each Obligor will promptly pay or cause to be paid any valid, final judgment rendered upon the conclusion of the relevant proceeding, if any, enforcing such Tax and cause it to be satisfied of record.

 

12.14

Limitation on Indebtedness

The Obligors shall not incur Indebtedness other than the following (with any baskets measured in the aggregate among all the Obligors):

 

  (a)

Senior Debt, including any reborrowing of any Working Capital Debt in accordance with its terms;

 

-110-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

Replacement Debt or other Indebtedness expressly contemplated by a Material Project Agreement (including guarantees permitted by Section 12.15 (Guarantees));

 

  (c)

[reserved];

 

  (d)

Permitted Additional Working Capital Debt;

 

  (e)

Subordinated Debt in an amount not to exceed $675 million in the aggregate;

 

  (f)

intercompany Indebtedness between or among the Obligors, all of which shall be Subordinated Debt;

 

  (g)

Indebtedness incurred under Permitted Hedging Instruments not covered under clause (a) above;

 

  (h)

Indebtedness in respect of any bankers’ acceptances, letters of credit, warehouse receipts or similar facilities, in each case, incurred in the ordinary course of business;

 

  (i)

purchase money Indebtedness and capital leases or guarantees of the same, in a principal amount not exceeding $100 million in the aggregate to finance the purchase or lease of assets for the Development other than those financed with the proceeds of Senior Debt; provided that if such obligations are secured, they are secured only by Liens upon the assets being financed or the proceeds of such assets;

 

  (j)

any other unsecured Indebtedness incurred after the Project Phase 1 Completion Date in an aggregate amount outstanding at any one time not to exceed $200 million for general corporate purposes (including, for the avoidance of doubt, to reduce the principal amount relating to any revolving loans under a Senior Debt Instrument to $0 as and when required under the terms of such Senior Debt Instrument);

 

  (k)

to the extent constituting Indebtedness, indebtedness arising from honoring by a bank or other financial institution of a check, draft or similar instrument drawn against insufficient funds in the ordinary course or other cash management services in the ordinary course of business;

 

  (l)

Indebtedness in respect of netting services, overdraft protections and otherwise in connection with deposit accounts;

 

  (m)

contingent liabilities incurred in the ordinary course of business, including the acquisition or sale of goods, services, supplies or merchandise in the normal course of business, the endorsement of negotiable instruments received in the normal course of business and indemnities provided under any of the Transaction Documents;

 

-111-

Plaquemines – Amended & Restated Common Terms Agreement


  (n)

to the extent constituting Indebtedness, obligations in respect of performance bonds, bid bonds, appeal bonds, surety bonds, indemnification obligations, obligations to pay insurance premiums, take-or-pay obligations contained in supply agreements and similar obligations incurred in the ordinary course of business;

 

  (o)

trade debt, trade accounts, purchase money obligations or other similar Indebtedness incurred in the ordinary course of business, which:

 

  (i)

is not more than 90 days past due; or

 

  (ii)

is being contested in good faith and by appropriate proceedings;

 

  (p)

Indebtedness consisting of the financing of insurance premiums in customary amounts consistent with the operations and business of the Obligors in the ordinary course of business;

 

  (q)

to the extent constituting Indebtedness, the transactions contemplated by, or in respect of, the Bridge Lease Agreement;

 

  (r)

operating leases that are re-categorized as Capital Leases as a result of ASC 842; and

 

  (s)

other Indebtedness incurred with the consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties, together with any refinancing thereof.

 

12.15

Guarantees

No Obligor shall guarantee the obligations of others (other than the other Obligor) except for guarantees expressly contemplated by a Finance Document, a Material Project Agreement or a material Permit.

 

12.16

Limitation on Liens

The Obligors shall not assume, incur, permit or suffer to exist any Lien on any of its assets, whether now owned or hereafter acquired, except for Permitted Liens.

 

-112-

Plaquemines – Amended & Restated Common Terms Agreement


12.17

Sale of Project Property

No Obligor shall sell, lease or otherwise dispose of Project Property, in one transaction or a series of transactions, in excess of $100 million per year without the consent of the Intercreditor Agent and no Obligor shall sell, lease or otherwise dispose of the Gator Express Pipeline, except in each case that no consent of the Intercreditor Agent shall be required for:

 

  (a)

dispositions in compliance with any applicable court or governmental order;

 

  (b)

dispositions of obsolete, superfluous or replaced assets, or assets that are not, or cease to be, necessary for the construction and operation of the Project Facilities substantially in the manner contemplated in this Agreement;

 

  (c)

sales or other dispositions of LNG in accordance with any LNG SPAs as permitted under the Finance Documents;

 

  (d)

sales of Gas in the ordinary course of business;

 

  (e)

sales, transfers or other dispositions of Authorized Investments;

 

  (f)

Restricted Payments made in accordance with the Finance Documents;

 

  (g)

liquefaction and other services in the ordinary course of business;

 

  (h)

settlement, release, waiver or surrender of contract, tort or other claims in the ordinary course of business or a grant of a Lien not prohibited by the Finance Documents;

 

  (i)

the transfer or novation of Permitted Hedging Instruments in accordance with the Finance Documents;

 

  (j)

conveyance of gas interconnection or metering facilities to gas transmission companies and conveyance of electricity substations to electricity providers pursuant to its electricity purchase arrangements for operating the Project Facilities; and

 

  (k)

dispositions of other Project Property if an Obligor replaces such Project Property within 180 days following such disposition or has obtained a commitment to replace such Project Property within 180 days following such disposition and replaces such Project Property within 270 days following such disposition.

Proceeds of any such disposition by the Borrower pursuant to this Section 12.17 (Sale of Project Property) shall be deposited in the Phase 1 Pre-Completion Revenues Account, the Phase 2 Pre-Completion Revenues Account or the Revenue Account; provided that proceeds of any disposition of assets requiring mandatory prepayment under Section 3.4 (Mandatory Prepayments) shall be deposited into the Additional Proceeds Prepayment Account.

 

-113-

Plaquemines – Amended & Restated Common Terms Agreement


12.18

Merger, Division, Liquidation and Sale of All Assets

No Obligor shall liquidate itself, enter into any merger or division or sell or otherwise transfer all or substantially all its assets to any Person or any series of any Obligor (including by operation of law), except to any series of Obligor who agrees in writing to become an Obligor hereunder.

 

12.19

Limitation on Investments and Loans

No Obligor shall make any investments, loans or advances to any Person other than:

 

  (a)

Authorized Investments;

 

  (b)

by way of trade credit in the ordinary course of business;

 

  (c)

as specifically contemplated under the Finance Documents;

 

  (d)

as expressly contemplated by the terms of the Material Project Agreements then in effect to which it is a party;

 

  (e)

surety and performance bonds and workers’ compensation, utility, lease, tax, performance and similar deposits, advance payments in the ordinary course of business on usual commercial terms and prepaid expenses in the ordinary course of business, including cash deposits incurred in connection with natural gas purchases;

 

  (f)

[reserved];

 

  (g)

investments pursuant to Permitted Hedging Instruments;

 

  (h)

investments, loans or advances among and between the Obligors; provided that amounts owing thereunder are Subordinated Debt; and

 

  (i)

loans from either the Borrower or the Guarantor to Pledgor, the Sponsor or their respective Affiliates (other than Guarantor or Borrower), but only to the extent that such loans are made with cash available to the Borrower to make a Restricted Payment and after meeting the test to make Restricted Payments under Section 11.1 (Conditions to Restricted Payments).

 

12.20

Nature of Business

 

  (a)

The Obligors shall not (i) change the limited nature of their business in any material respect from that contemplated by the Common Terms Agreement and the Common Security and Account Agreement in the form existing on the Initial Closing Date or (ii) engage in retail sales of natural gas in such a manner and to such an extent so as to cause either Obligor to become subject

 

-114-

Plaquemines – Amended & Restated Common Terms Agreement


to regulation as a “gas utility” under the Louisiana Government Rules. In the event either Obligor engages in retail sales of natural gas in a manner that would cause it to become a “holding company” or a “subsidiary company” of a “holding company” (each as defined under PUHCA), it shall (A) comply in all material respects with all applicable provisions of PUHCA and (B) use commercially reasonable efforts to obtain an exemption from regulation under PUHCA.

 

  (b)

The Borrower shall not permit to exist any Subsidiary of the Borrower.

 

  (c)

The Guarantor shall not permit to exist any Subsidiary of the Guarantor.

 

12.21

Transactions with Affiliates

No Obligor shall directly or indirectly enter into any transaction or agreement with or for the benefit of an Affiliate (including guarantees and assumptions of obligations of an Affiliate) in relation to the Development, except:

 

  (a)

agreements that are Material Project Agreements or required or contemplated by any Material Project Agreement;

 

  (b)

any other agreement relating to the Development entered into prior to the Initial Closing Date that was disclosed on Schedule J (Transactions With Affiliates) to the Original Common Terms Agreement;

 

  (c)

to the extent required by applicable law or regulation; or

 

  (d)

transactions or agreements entered into on fair and commercially reasonable terms (from the perspective of the relevant Obligor) that (i) could not reasonably be expected to cause a Material Adverse Effect and (ii) are not materially less favorable in the aggregate to such Obligor than such Obligor would obtain in a comparable agreement with independent parties acting at arm’s length (or, if there is no comparable arm’s-length transaction, then on terms reasonably determined by the board of managers of the Borrower to be fair and reasonable);

 

  provided

that:

 

  (i)

this covenant shall not apply to (A) transactions between or among the Obligors, (B) any issuance of equity interests of any Obligor to its direct parent and (C) Permitted Payments; and

 

  (ii)

any such agreement that constitutes a Subsequent Material Project Agreement shall be subject to the terms of Section 12.5 (Material Project Agreements).

 

-115-

Plaquemines – Amended & Restated Common Terms Agreement


12.22

Hedging Arrangements

 

  (a)

No Obligor shall enter into Hedging Instruments other than Permitted Hedging Instruments.

 

  (b)

The Borrower shall enter into and thereafter maintain in full force and effect, from time to time, one or more interest rate Permitted Hedging Instruments:

 

  (i)

no later than 45 days following the Upsize Closing Date, with respect to no less than 50%, but no more than 105% (calculated on a weighted average basis) of the projected aggregate outstanding balance of the Senior Debt projected to be outstanding (as determined by the Borrower in accordance with the Base Case Forecast) until the latest payment date occurring at the expiration of the 20-year notional amortization period; and

 

  (ii)

no later than 45 days following the Upsize Closing Date, with respect to no less than 75%, but no more than 105% (calculated on a weighted average basis) of the projected aggregate outstanding balance of the Senior Debt projected to be outstanding (as determined by the Borrower in accordance with the Base Case Forecast) until the Maturity Date;

provided that for purposes of calculating such percentage in the foregoing sub-clauses (i) and (ii) above, (w) the principal balance of the Working Capital Facility and/or Working Capital Debt shall be excluded, (x) any obligations incurred under the Permitted Senior Debt Hedging Instruments shall be excluded, and (y) any such Senior Debt which bears a fixed interest rate shall be deemed subject to a Permitted Hedging Instrument.

 

  (c)

If, due to a mandatory prepayment made in accordance with Section 3.4 (Mandatory Prepayments), a voluntary prepayment made in accordance with Section 3.5 (Voluntary Prepayments) or otherwise, the aggregate notional amount of the Permitted Hedging Instruments (which, for the avoidance of doubt, shall only include Permitted Hedging Instruments that are Interest Rate Hedging Instruments) on any Quarterly Payment Date is greater than 105% (or, if 105% hedging is not permitted by applicable law, 100%) (in each case, calculated on a weighted average basis) of the projected aggregate outstanding balance of the Senior Debt, within 45 days, the Borrower shall reduce the amount that is hedged under the Permitted Hedging Instruments (in the proportion allocated to each Permitted Hedging Instrument as may be determined by the Borrower as long as the Borrower has used commercially reasonable efforts to allocate the reduction pro rata among each Permitted Hedging Instrument, after taking into account any

 

-116-

Plaquemines – Amended & Restated Common Terms Agreement


  back-to-back or offsetting arrangements related thereto) such that the aggregate notional amount of the Permitted Hedging Instruments is not more than 105% (or, if 105% hedging is not permitted by applicable law, 100%) (in each case, calculated on a weighted average basis) of the projected aggregate outstanding balance of the Senior Debt on such Quarterly Payment Date (any such amount of the Permitted Hedging Instruments that is required to be so reduced, a “Hedging Excess Amount).

 

12.23

Accounts

 

  (a)

No Obligor shall maintain any accounts in contravention of Article 4 (Cash Flow and Accounts) of the Common Security and Account Agreement.

 

  (b)

(i) All revenues of the Obligors shall be deposited in accordance with the Common Security and Account Agreement and (ii) the Obligors shall direct third parties to deposit all amounts required to be paid to the Obligors in accordance with the Common Security and Account Agreement.

 

12.24

Separateness

Each Obligor shall at all times:

 

  (a)

observe all applicable entity procedures necessary to maintain its separate existence and formalities, including:

 

  (i)

maintaining minutes or records of meetings of the members and/or managers of the Obligor;

 

  (ii)

acting on behalf of itself only pursuant to due authorization of the members and/or managers, including, when applicable, any independent managers or members; and

 

  (iii)

conducting its own business in its own name and through authorized agents pursuant to its Constitutional Documents;

 

  (b)

allocate fairly and reasonably any shared expenses, including overhead for shared office space or common employees (if any);

 

  (c)

use separate stationery, invoices and checks bearing its own name;

 

  (d)

prepare and maintain its own full and complete books, accounting records (including books of account and payroll, if any) and other documents and records, in each case which are separate and apart from the books, accounting records and other documents and records of the Sponsor or any Affiliate thereof (other than the other Obligor);

 

-117-

Plaquemines – Amended & Restated Common Terms Agreement


  (e)

maintain separate bank accounts in its own name or otherwise pursuant to the Finance Documents and make all investments by or on behalf of an Obligor solely in its name except as otherwise provided by the Finance Documents;

 

  (f)

separate its property and not allow funds or other assets to be commingled with the funds and other assets of, held by, or registered in the name of the Sponsor or any Affiliate thereof (other than the other Obligor), and maintain its assets in such a manner that it is not costly or difficult to identify or ascertain such assets, all except to the extent otherwise provided by the Finance Documents;

 

  (g)

not hold itself out as being liable for the debts of the Sponsor or any Affiliate thereof (other than the other Obligor) and not guarantee the debts of the Sponsor or any Affiliate thereof (other than the other Obligor) except as permitted by the Finance Documents;

 

  (h)

not acquire or assume obligations or securities of, or make loans or advances to, any of its Affiliates except as required under the Finance Documents;

 

  (i)

maintain separate financial statements, showing its assets and liabilities separate and apart from those of any other Person, and not have its assets listed on the balance sheet of any other Person; provided that such Obligor may also report its financial statements on a consolidated or combined basis with one or more of its Affiliates in accordance with GAAP so long as appropriate notation is made on such consolidated financial statements to indicate the separateness of the Obligors from such Affiliate(s) and to disclose the separate nature of the Obligors’ Indebtedness;

 

  (j)

prepare and file its own tax returns separate from those of any Person except to the extent that the Obligor is treated as a “disregarded entity” for tax purposes and is not required to file tax returns under applicable law;

 

  (k)

pay its own liabilities and expenses out of its own assets (except as provided under the Finance Documents);

 

  (l)

maintain adequate capitalization in light of its contemplated business and obligations;

 

  (m)

hold itself out to third parties as a legal entity, separate and distinct and independent from any other entity, conduct its own business solely under its name and correct any known misunderstanding as to the separateness of the Obligors from any other Person; and

 

-118-

Plaquemines – Amended & Restated Common Terms Agreement


  (n)

have and maintain Constitutional Documents which comply with the requirements of this Section 12.24 (Separateness),

provided that no limitation in this Section 12.24 (Separateness) shall apply to the Obligors as among one another.

 

12.25

Historical DSCR

 

  (a)

The Obligors shall not permit the Historical DSCR for the most recent 12- month period ending as of the end of any fiscal quarter from and following the First Upsize Repayment Date after the Project Phase 2 Completion Date to be less than 1.15:1.

 

  (b)

Notwithstanding anything in clause (a) above to the contrary, if the Historical DSCR for the most recent 12-month period ending at the end of any fiscal quarter following the First Upsize Repayment Date after the Project Phase 2 Completion Date is less than 1.15:1 but greater than 1:1, any direct or indirect owner of the Obligors shall have the right to provide cash to the Obligors not later than ten Business Days following the delivery of the calculation of such Historical DSCR in the form of equity contributions or Subordinated Debt in order to increase the Historical DSCR to 1.15:1; provided that such right may not be exercised for more than two consecutive fiscal quarters nor, with respect to each Senior Debt Instrument, more than four times over the term of such Senior Debt Instrument.

 

12.26

Auditors

The Borrower shall engage Ernst & Young LLP and shall not replace such auditor except with another independent certified public accounting firm of recognized national standing.

 

12.27

Gas Transportation Arrangements; Gas Purchase Arrangements

 

  (a)

The Borrower shall comply in all material respects with the gas sourcing plan attached as Schedule K (Gas Sourcing Plan) hereto, as may be updated (i) by the Borrower on a semi-annual basis in relation to the list of Qualified Gas Suppliers as set forth in the definition thereof or (ii) from time to time otherwise by mutual agreement by the Borrower and the Intercreditor Agent (acting on the instruction of the Requisite Intercreditor Parties, whose consent to updates of such gas sourcing plan shall not be unreasonably withheld, conditioned or delayed if determined to be reasonable by the Market Consultant and/or Independent Engineer, as appropriate).

 

-119-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

The Borrower shall deliver to the Intercreditor Agent and the Credit Facility Agent quarterly reports summarizing firm natural gas supply and transport capacity and associated volumes.

 

12.28

Insurance Covenant

 

  (a)

To the extent available to the Obligors on Reasonable Commercial Terms and taking into account requirements of applicable law and regulation, the Obligors shall obtain and maintain, or cause to be obtained and maintained, at all times, the commercial insurance coverage set forth in Schedule L (Schedule of Minimum Insurance) hereto describing the minimum insurance required to be held by the Obligors (the “Schedule of Minimum Insurance”). “Reasonable Commercial Terms” means commercial insurance market terms which are reasonable having regard to the nature of the risk insured, the cost of maintaining insurance against that risk and the interests of the Obligors and the Secured Parties under the Finance Documents. Without prejudice to any other element, the cost of maintaining insurance alone is not a determinant of Reasonable Commercial Terms. Disputes as to whether the relevant insurance is available on Reasonable Commercial Terms, is in accordance with applicable laws or regulations or complies with the Schedule of Minimum Insurance shall be referred to an independent insurance expert from the agreed list of independent insurance experts attached as Schedule M (Independent Insurance Experts) hereto, as such list may be updated from time to time by mutual agreement by the Borrower and the Intercreditor Agent.

 

  (b)

With respect to all Mortgaged Property located in a special flood hazard area (as defined pursuant to applicable flood insurance regulations), the Borrower will obtain and maintain at all times flood insurance for all Collateral located on such property as may be required under the Flood Program and will provide to each Facility Lender evidence of compliance with such requirements as may be reasonably requested by such Lender. The timing and process for delivery of such evidence will be as set forth in the Schedule of Minimum Insurance. If any Building (as defined in the applicable flood insurance regulations) or Manufactured (Mobile) Home (as defined in the applicable flood insurance regulations) constitutes property that is secured for the benefit of the Senior Creditors pursuant to a mortgage required under the Finance Documents, the Borrower shall maintain in full force and effect flood insurance for such property, structures and contents in such amount and for so long as required by applicable flood insurance regulations.

 

-120-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

The Borrower will provide 45 days prior written notice to the Intercreditor Agent and each Facility Agent before it commences construction of any Building (as defined in the applicable flood insurance regulations) after the Initial Closing Date and before it affixes any Manufactured (Mobile) Home (as defined in the applicable flood insurance regulations) after the Initial Closing Date to any property that is secured for the benefit of the Senior Creditors pursuant to a mortgage required under the Finance Documents and that is located in a special flood hazard area (as defined pursuant to applicable flood insurance regulations). The preceding sentence will not affect the obligations of the Borrower under Section 12.28(b) (Insurance Covenant) above to maintain flood insurance.

 

  (d)

The Borrower will provide 45 days prior written notice to the Intercreditor Agent before it acquires any Real Estate that is permitted under the Finance Documents and that will be secured for the benefit of the Senior Creditors pursuant to a deed of trust required under the Finance Documents. The preceding sentence will not affect the obligations of the Borrower under Section 12.28(b) (Insurance Covenant) above to maintain flood insurance.

 

12.29

Certain Real Property Rights; Real Property Documents; Leases

 

  (a)

Each Obligor shall obtain appropriate releases, consents, crossing agreements or other like acknowledgements from the holders of the rights set forth on Schedule V (Schedule of Certain Real Property Rights) to the extent necessary for the Development.

 

  (b)

Each Obligor shall comply with its material contractual obligations under each Real Property Document then in effect to which it is a party, and, subject to Section 12.5(e) (Material Project Agreements), enforce against all other Persons that are parties thereto such Obligor’s material rights and material covenants and obligations under such Real Property Document.

 

  (c)

No Obligor shall agree to any amendment or modification of, or waiver relating to, any Real Property Document to which it is a party that could reasonably be expected to have a Material Adverse Effect or that would materially breach the terms of the Finance Documents.

 

12.30

Margin Regulation

No Obligor shall use any portion of the proceeds of the Loans to purchase or carry any Margin Stock or to extend credit to others for the purpose of purchasing or carrying any Margin Stock. No Obligor shall use the proceeds of the Loans in a manner that could reasonably be expected to violate or be inconsistent with the provisions of Regulation T, Regulation U or Regulation X.

 

-121-

Plaquemines – Amended & Restated Common Terms Agreement


12.31

Further Assurances

Each of the Obligors shall take all action reasonably required to preserve the validity, perfection and priority of the Liens purported to be granted to the Collateral Agent for the benefit of the Secured Parties pursuant to the Security Documents (subject to Permitted Liens). The Borrower shall promptly perform or cause to be performed any and all acts and execute or cause to be executed any and all documents (including UCC financing statements and UCC continuation statements):

 

  (a)

as are reasonably requested by the Collateral Agent for filing under the provisions of the UCC or any other Government Rule that are necessary or reasonably advisable to maintain in favor of the Collateral Agent, for the benefit of the Secured Parties, Liens on the Collateral that are duly perfected in accordance with all applicable Government Rules for the purposes of perfecting the first priority Lien (subject to Permitted Liens) created, or purported to be created, in favor of the Collateral Agent or the Secured Parties under this Agreement or any other Finance Documents;

 

  (b)

as are reasonably requested by the Collateral Agent for the purposes of ensuring the validity, enforceability and legality of this Agreement or any other Finance Document and the rights of the Secured Parties and the Collateral Agent hereunder or thereunder;

 

  (c)

as are reasonably requested by the Collateral Agent for the purposes of enabling or facilitating the proper exercise of the rights and powers granted to the Secured Parties and the Collateral Agent under this Agreement or any other Finance Document; or

 

  (d)

as are reasonably requested by the Collateral Agent to carry out the intent of, and transactions contemplated by, this Agreement and the other Finance Documents.

 

12.32

As-Built Survey

Within 120 days after the Project Phase 2 Completion Date, Borrower shall deliver to the Intercreditor Agent an as-built survey of the LNG Facility Site and the LNG Facility located on it in accordance with and meeting all requirements and information required for the initial survey referred to in Section 4.1(j)(i) (Conditions to Initial Closing Date and Initial Advance – Real Property).

 

12.33

ERISA

The Obligors shall not establish, maintain, contribute to or become obligated to contribute to any Pension Plan or Multiemployer Plan.

 

-122-

Plaquemines – Amended & Restated Common Terms Agreement


13.

CONSULTANTS

 

  13.1

Appointment of Consultants

The common CCRA Consultant, the common Independent Engineer, the common Insurance Advisor, the common Environmental Consultants and the common Market Consultant (the “Consultants”), as of the Upsize Closing Date, are listed in Schedule N (Senior Creditors’ Advisors and Consultants) hereto. Each such Consultant shall be deemed to be retained by, and shall be solely responsible to and for the benefit of, the Facility Lenders. The Consultants may also act for the benefit of, and deliver reports to, the Indenture Trustee, Senior Noteholders, the Intercreditor Agent and/or the initial purchasers of the Senior Notes.

 

  13.2

Replacement and Fees

 

  (a)

In accordance with the terms of each such Consultant’s engagement letter, the Borrower (with the consent of the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties, such consent not to be unreasonably withheld, conditioned or delayed) or the Intercreditor Agent acting on the instructions of the Requisite Intercreditor Parties and, subject to clause (b) below, following good faith consultation with the Borrower, may remove from time to time any one or more of such Consultants, and the Borrower shall engage such replacements as the Intercreditor Agent, acting on the instructions of the Requisite Intercreditor Parties, may choose (with the prior consent of the Borrower, such consent not to be unreasonably withheld, conditioned or delayed). Such replacement is subject to confirmation at the time of its appointment of no conflict of interest that would prevent a replacement Consultant from acting for the Facility Lenders. The replacement of any Consultant shall not increase the annual limits referred to in clause (c) below.

 

  (b)

Notwithstanding clause (a) above, in the event that a Loan Facility Event of Default or Unmatured Loan Facility Event of Default has occurred and is Continuing that is reasonably connected to a matter on which a Consultant may be requested by the Senior Creditors or their representatives to advise, for the duration of such default, the Borrower’s consent rights under such clause (a) above shall cease and the Intercreditor Agent, acting reasonably on the instructions of the Requisite Intercreditor Parties, shall have the right to remove any Consultant and appoint a replacement Consultant.

 

  (c)

All fees and expenses of the Consultants (whether the original ones or replacements) shall, subject in each case to the applicable Consultant’s engagement letter, be paid by the Borrower. Any reasonable fees incurred by any Consultant to provide services required under the Finance Documents but not otherwise within the scope of work under the applicable

 

-123-

Plaquemines – Amended & Restated Common Terms Agreement


  engagement letter shall be paid by the Borrower subject to certain annual limits, if any, to be specified in such engagement letter (except that such annual limits shall not apply in relation to any work (i) investigating a Loan Facility Event of Default or Unmatured Loan Facility Event of Default, or (ii) in respect of any waiver request by the Borrower, both of which instead shall be subject to reasonable work plans, budgets and compensation limits to be agreed by such Consultant in consultation with the Intercreditor Agent and advised to the Borrower). Except in such cases, the consent of the Borrower (such consent not to be unreasonably withheld, conditioned or delayed) shall be required for a Consultant to perform additional work not otherwise contemplated by the terms of the relevant engagement letter or that would otherwise cause the reasonable fees and expenses of such Consultant to exceed the annual limits set forth in the relevant engagement letter.

 

  13.3

Access

 

  (a)

After the Upsize Closing Date, Site visits to the Project Facilities may be conducted in accordance with clause (b) below upon reasonable prior request by:

 

  (i)

the Independent Engineer and, if requested, the Facility Agent (or one alternative representative) for each Senior Creditor Group comprised of Facility Lenders, any such visits to be coordinated between the Independent Engineer and the applicable Facility Agents up to two (2) times (which shall be reasonably spaced within the applicable period) per calendar year, except to the extent additional visits are made in connection with the occurrence of a Loan Facility Event of Default or an Unmatured Loan Facility Event of Default; and

 

  (ii)

any Consultant to the extent reasonably required for such Consultant to provide any report, certificate or confirmation explicitly contemplated by the terms of the Finance Documents.

 

  (b)

Site visits shall be granted during normal business hours, in a manner that does not unreasonably disrupt the construction or operation of the Project Facilities in any respect, and subject to the confidentiality provision of Section 12.6 (Confidentiality) of the Common Security and Account Agreement and Section 23.7 (Confidentiality) below and safety arrangements and shall be at the cost and expense of the Obligors.

 

-124-

Plaquemines – Amended & Restated Common Terms Agreement


14.

CONDITIONS TO COMPLETION; PROJECT COMPLETION DATES WATERFALLS

 

  14.1

Conditions to Occurrence of the Project Phase 1 Completion Date

The occurrence of the Project Phase 1 Completion Date is subject to the satisfaction of each of the following, and no other, common conditions (or waiver thereof by the Intercreditor Agent (acting on the instruction of the Requisite Intercreditor Parties)):

 

  (a)

Notice of Project Completion

Receipt by the Intercreditor Agent of a duly executed and completed notice of project completion from the Borrower certifying that the conditions in this Section 14.1 (Conditions to Occurrence of the Project Phase 1 Completion Date) have been met.

 

  (b)

Borrower Certificate

Receipt by the Intercreditor Agent of a certificate of the Borrower certifying that:

 

  (i)

each of the Repeated Representations of the Obligors is true and correct in all material respects, except for representations and warranties that are qualified by materiality or Material Adverse Effect, which shall be true and correct in all respects, on and as of the Project Phase 1 Completion Date as if made on and as of such date (or, if stated to have been made solely as of an earlier date, as of such earlier date);

 

  (ii)

no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing on such date or is expected to result from the occurrence of the Project Phase 1 Completion Date;

 

  (iii)

no default by an Obligor exists under any Material Project Agreement that could reasonably be expected to have a Material Adverse Effect and, to the Knowledge of each Obligor, no default by a Material Project Counterparty exists under any Material Project Agreement that could reasonably be expected to have a Material Adverse Effect;

 

  (iv)

to the Knowledge of each Obligor, no event of force majeure (as defined in the applicable Material Project Agreement) has occurred and is Continuing under any Material Project Agreement, the consequences of which could reasonably be expected to have a

 

-125-

Plaquemines – Amended & Restated Common Terms Agreement


  Material Adverse Effect; provided that, in the case of any Phase 2 Material Project Agreement, any force majeure event shall be excluded from this clause (iv) so long as such force majeure event could not reasonably be expected to result in the Project Phase 2 Completion Date not occurring prior to the Phase 2 LNG Facility Date Certain; and

 

  (v)

(i) the Required LNG SPAs (including guarantees or other forms of credit support required by their terms), (ii) the Pipeline Service Agreements, (iii) the Gas Transportation Agreements (or Replacement Material Contract in respect thereof), (iv) the Service Agreements described in clauses (a) through (d) of the definition thereof (or Replacement Material Contract in respect thereof) and (v) the gas supply agreements (including guarantees or other forms of credit support required by their terms) that collectively are sufficient to enable the Borrower to meet its obligations under the Required LNG SPAs are, in each case, in full force and effect, enforceable against the parties thereto in accordance with such contract’s terms, except as limited by general principles of equity and bankruptcy, insolvency and similar laws.

 

  (c)

Physical Completion Certificate

Receipt by the Intercreditor Agent of a certificate from the Independent Engineer confirming:

 

  (i)

that (x) Facility Substantial Completion (as such term is defined in the Phase 1 EPC Contract) has occurred pursuant to the Phase 1 EPC Contract (subject to the completion of any punch list items under the Phase 1 EPC Contract) and (y) Mechanical Completion (as such term is defined in the Sunland Pipeline Construction Contract) has occurred pursuant to the Sunland Pipeline Construction Contract;

 

  (ii)

the applicable performance tests under each of the Phase 1 Material Construction Contracts have been successfully passed in accordance with such Phase 1 Material Construction Contract;

 

  (iii)

the Phase 1 Lenders’ Reliability Test has been passed in accordance with the test criteria set out in Schedule O – 1 (Phase 1 Lenders’ Reliability Test Criteria) hereto and the “LRT Completion Certificate” contemplated thereby has been delivered to the Intercreditor Agent;

 

-126-

Plaquemines – Amended & Restated Common Terms Agreement


  (iv)

in addition to funds required to achieve the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain (and without taking into account any funds or commitments used to satisfy the Contingency Reserve Amount on a pro forma basis after the Project Phase 1 Completion Date) the Borrower has access to sufficient funds to fund the Phase 1 Punch List Amount; and

 

  (v)

the Phase 1 Project Facilities are Operational.

 

  (d)

Commercial Operation Date

Receipt by the Intercreditor Agent of a duly executed certificate of the Borrower certifying that the Commercial Operation Date under each of the Required LNG SPAs with respect to the Phase 1 LNG Facility then in effect has timely occurred.

 

  (e)

Payment

Receipt by the Collateral Agent of evidence that the Borrower shall have paid all amounts due and payable under each of the Phase 1 Material Construction Contracts other than: (i) amounts required to complete the construction and start-up of the Phase 1 Project Facilities (in respect of which the Borrower shall have sufficient funds available to it as contemplated by clause (c)(iv) above), (ii) amounts properly withheld or retained by the Borrower in accordance with the terms and conditions of such Phase 1 Material Construction Contracts, (iii) any bonus or other amounts payable under such Phase 1 Material Construction Contracts after Final Completion (as defined in the Phase 1 EPC Contract) or similar milestones in the Phase 1 Material Construction Contracts and (iv) any disputed amount under the Phase 1 Material Construction Contracts; provided that, in the event that any amount under any Phase 1 Material Construction Contract is disputed by the Borrower, the Borrower shall have reserved funds in an amount determined by the Borrower acting in good faith for payment of any disputed amounts that may reasonably be expected to be determined or agreed to be payable by the Borrower (such disputed amount(s), together with the Phase 1 Punch List Amount, the “Phase 1 Reserve Amounts”).

 

  (f)

Title Policy Endorsement

Receipt by the Intercreditor Agent of a Disbursement Endorsement meeting the requirements set forth in the definition thereof for the delivery of such endorsement on the Project Phase 1 Completion Date.

 

-127-

Plaquemines – Amended & Restated Common Terms Agreement


  (g)

Insurance

Receipt by the Intercreditor Agent of a certificate from the Borrower (confirmed in writing to be reasonable by the Insurance Advisor) confirming that all insurance premium payments due and payable as of the Project Phase 1 Completion Date have been paid and that the insurance then in place relating solely to the Phase 1 Project Facilities is in effect and complies with the then-applicable requirements of Schedule L (Schedule of Minimum Insurance) hereto, and certificates of insurance, binders or other documentation evidencing such insurance.

 

  (h)

Permits

Receipt by the Intercreditor Agent of evidence that all material Permits necessary for the Development (as set forth on Schedule F (Material Permits)) (and, in the case of any Export Authorization, such Export Authorization to the extent that it is a Required Export Authorization):

 

  (i)

have been obtained and are in full force and effect;

 

  (ii)

are held in the name of an Obligor or such third party as set forth on Schedule F (Material Permits) hereto and as allowed pursuant to applicable law or regulations;

 

  (iii)

are not the subject of any pending appeal (or if subject to any appeal, such appeal does not have a reasonable probability of success and the applicable permit remains effective during such appeal) and all applicable fixed time periods for appeal set forth in the Government Rules pursuant to which such Permits were issued have expired or are Permits that do not have limits on appeal periods under applicable law or regulation; and

 

  (iv)

are free from conditions or requirements (A) the compliance with which could reasonably be expected to have a Material Adverse Effect or (B) that the applicable Obligor does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development except to the extent that failure to so satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect.

 

  (i)

Phase 1 Project Facilities Placed in Service

Receipt by the Intercreditor Agent of evidence that the Obligors have received from FERC a notice, order or other written communication authorizing it to place the facilities comprising the Phase 1 Project Facilities in service, and that the Phase 1 Project Facilities shall have been placed in service.

 

-128-

Plaquemines – Amended & Restated Common Terms Agreement


  (j)

[Reserved]

 

  (k)

Lien Waivers

Receipt by the Intercreditor Agent of: (i) copies of Lien Waivers as have then been (and only to the extent) required pursuant to each Phase 1 Material Construction Contract and Site Works Contract; (ii) copies of one or more notices of termination of work filed pursuant to the Louisiana Private Works Act in the mortgage records of Plaquemines Parish, Louisiana, certifying termination of the work under the Phase 1 EPC Contract, including the installation, testing and start-up of equipment supplied to the Borrower pursuant to other Phase 1 Material Construction Contracts (other than those Phase 1 Material Construction Contracts referred to in clause (iii) of this Section 14.1(k) (Conditions to Occurrence of Project Phase 1 Completion Date – Lien Waivers)); (iii) copies of one or more notices of termination of work filed pursuant to the Louisiana Private Works Act in the mortgage records of Plaquemines Parish, Louisiana, certifying termination of the work (A) under the Phase 1 Material Construction Contracts described in clauses (b), (g), (h), (i) and (j) of the definition thereof, and (B) to the extent notices of termination thereof have not been previously provided to the Intercreditor Agent, under the Site Works Contracts; and (iv) a lien certificate by the recorder of mortgages of Plaquemines Parish, Louisiana, issued after the period for filing a statement of claim or privilege under the Louisiana Private Works Act has expired and confirming that no statements of claim or privilege are of record (other than Permitted Liens) for work performed under the Phase I EPC Contract or any Phase 1 Material Construction Contract.

 

  (l)

Initial Operating Budget

The Intercreditor Agent shall have received the initial Operating Budget required pursuant to Section 10.5 (Operating Budget).

 

  (m)

Notes

The Intercreditor Agent shall have received copies of the promissory notes requested by the Credit Facility Lenders pursuant to the Credit Facility Agreement duly authorized, executed and delivered by the Borrower.

 

  (n)

Senior Facilities Debt Service Reserve Account

The Senior Facilities Debt Service Reserve Account shall have been funded in an amount equal to the Senior Facilities Reserve Amount.

 

  (o)

[Reserved]

 

-129-

Plaquemines – Amended & Restated Common Terms Agreement


  (p)

Senior Debt/Equity Ratio

The Senior Debt/Equity Ratio shall be no greater than 75:25, as certified by the Borrower.

 

  (q)

Additional Material Project Agreements

The Intercreditor Agent shall have received copies of any Material Project Agreements and required material Permits entered into or issued after the Initial Closing Date, to the extent not previously delivered by the Borrower to the Intercreditor Agent.

 

  14.2

Project Phase 1 Completion Date Transfers

On the Project Phase 1 Completion Date, amounts on deposit in the Phase 1 Pre- Completion Revenues Account shall be transferred to the Phase 2 Pre-Completion Revenues Account pursuant to Section 4.5(b)(iii) (Deposits and Withdrawals – Phase 1 Pre-Completion Revenues Account) of the Common Security and Account Agreement.

 

  14.3

Conditions to Occurrence of the Project Phase 2 Completion Date

The occurrence of the Project Phase 2 Completion Date is subject to the satisfaction of each of the following, and no other, common conditions (or waiver thereof by the Intercreditor Agent (acting on the instruction of the Requisite Intercreditor Parties)):

 

  (a)

Notice of Project Completion

Receipt by the Intercreditor Agent of a duly executed and completed notice of project completion from the Borrower certifying that the conditions in this Section 14.3 (Conditions to Occurrence of the Project Phase 2 Completion Date) have been met.

 

  (b)

Borrower Certificate

Receipt by the Intercreditor Agent of a certificate of the Borrower certifying that:

 

  (i)

each of the Repeated Representations of the Obligors is true and correct in all material respects, except for representations and warranties that are qualified by materiality or Material Adverse Effect, which shall be true and correct in all respects, on and as of the Project Phase 2 Completion Date as if made on and as of such date (or, if stated to have been made solely as of an earlier date, as of such earlier date);

 

-130-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing on such date or is expected to result from the occurrence of the Project Phase 2 Completion Date;

 

  (iii)

no default by an Obligor exists under any Material Project Agreement that could reasonably be expected to have a Material Adverse Effect and, to the Knowledge of each Obligor, no default by a Material Project Counterparty exists under any Material Project Agreement that could reasonably be expected to have a Material Adverse Effect;

 

  (iv)

to the Knowledge of each Obligor, no event of force majeure (as defined in the applicable Material Project Agreement) has occurred and is Continuing under any Material Project Agreement, the consequences of which could reasonably be expected to have a Material Adverse Effect; and

 

  (v)

(i) the Required LNG SPAs (including guarantees or other forms of credit support required by their terms), (ii) the Pipeline Service Agreements, (iii) the Gas Transportation Agreements (or Replacement Material Contract in respect thereof), (iv) the Service Agreements described in clauses (a) through (d) of the definition thereof (or Replacement Material Contract in respect thereof) and (v) the gas supply agreements (including guarantees or other forms of credit support required by their terms) that collectively are sufficient to enable the Borrower to meet its obligations under the Required LNG SPAs are, in each case, in full force and effect, enforceable against the parties thereto in accordance with such contract’s terms, except as limited by general principles of equity and bankruptcy, insolvency and similar laws.

 

  (c)

Physical Completion Certificate

Receipt by the Intercreditor Agent of a certificate from the Independent Engineer confirming:

 

  (i)

that the Project Phase 1 Completion Date has occurred;

 

  (ii)

that Facility Substantial Completion (as such term is defined in the Phase 2 EPC Contract) has occurred pursuant to the Phase 2 EPC Contract (subject to the completion of any punch list items under the Phase 2 EPC Contract);

 

-131-

Plaquemines – Amended & Restated Common Terms Agreement


  (iii)

the applicable performance tests under each of the Phase 2 Material Construction Contracts have been successfully passed in accordance with such Phase 2 Material Construction Contract;

 

  (iv)

the Lenders’ Reliability Test has been passed in accordance with the test criteria set out in Schedule O – 2 (Lenders’ Reliability Test Criteria) hereto and the “LRT Completion Certificate” contemplated thereby has been delivered to the Intercreditor Agent;

 

  (v)

the Borrower’s calculation of the Permitted Completion Costs and that the Borrower has reserved an amount sufficient for the Permitted Completion Costs; and

 

  (vi)

the Phase 2 LNG Facility is Operational.

 

  (d)

Commercial Operation Date

Receipt by the Intercreditor Agent of a duly executed certificate of the Borrower certifying that the Commercial Operation Date under each of the Required LNG SPAs with respect to the Phase 2 LNG Facility then in effect has timely occurred.

 

  (e)

Payment

Receipt by the Collateral Agent of evidence that the Borrower shall have paid all amounts due and payable under each of the Material Construction Contracts other than: (i) the Permitted Completion Amount (and any properly reserved amount in respect of Permitted Completion Costs for the Phase 1 Project Facilities), which is on deposit in the Construction Account after giving effect to the deposits and transfers set forth in Section 4.5(d) (Deposits and Withdrawals – Construction Account) of the Common Security and Account Agreement, (ii) amounts properly withheld or retained by the Borrower in accordance with the terms and conditions of such Phase 2 Material Construction Contracts, (iii) any bonus or other amounts payable under such Phase 2 Material Construction Contracts after Final Completion (as defined in the Phase 2 EPC Contract) or similar milestones in the Material Construction Contracts and (iv) any disputed amount under the Material Construction Contracts; provided that, in the event that any amount under any Material Construction Contract is disputed by the Borrower, the Borrower shall have reserved amounts adequate for payment thereof.

 

-132-

Plaquemines – Amended & Restated Common Terms Agreement


  (f)

Title Policy Endorsement

Receipt by the Intercreditor Agent of a Disbursement Endorsement meeting the requirements set forth in the definition thereof for the delivery of such endorsement on the Project Phase 2 Completion Date.

 

  (g)

Insurance

Receipt by the Intercreditor Agent of a certificate from the Borrower (confirmed in writing to be reasonable by the Insurance Advisor) confirming that all insurance premium payments due and payable as of the Project Phase 2 Completion Date have been paid and that the insurance then in place is in effect and complies with the then-applicable requirements of Schedule L (Schedule of Minimum Insurance) hereto, and certificates of insurance, binders or other documentation evidencing such insurance.

 

  (h)

Permits

Receipt by the Intercreditor Agent of evidence that all material Permits necessary for the Development (as set forth on Schedule F (Material Permits)) (and, in the case of any Export Authorization, such Export Authorization to the extent that it is a Required Export Authorization):

 

  (i)

have been obtained and are in full force and effect;

 

  (ii)

are held in the name of an Obligor or such third party as set forth on Schedule F (Material Permits) hereto and as allowed pursuant to applicable law or regulations;

 

  (iii)

are not the subject of any pending appeal (or if subject to any appeal, such appeal does not have a reasonable probability of success and the applicable permit remains effective during such appeal) and all applicable fixed time periods for appeal set forth in the Government Rules pursuant to which such Permits were issued have expired or are Permits that do not have limits on appeal periods under applicable law or regulation; and

 

  (iv)

are free from conditions or requirements (A) the compliance with which could reasonably be expected to have a Material Adverse Effect or (B) that the applicable Obligor does not expect to be able to satisfy on or prior to the commencement of the relevant stage of Development except to the extent that failure to so satisfy such condition or requirement could not reasonably be expected to have a Material Adverse Effect.

 

-133-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

Project Placed in Service

Receipt by the Intercreditor Agent of evidence that the Obligors have received from FERC a notice, order or other written communication authorizing it to place the facilities comprising the Phase 2 LNG Facility in service, and that the Phase 2 LNG Facility shall have been placed in service.

 

  (j)

Construction Contract Liquidated Damage Deposits

All Delay Liquidated Damages and Performance Liquidated Damages that were due and payable as of the Project Phase 2 Completion Date under each Material Construction Contract (excluding any damages that are the subject of a dispute) in excess of $10,000,000, shall have been deposited into the appropriate Account(s) and applied as set forth in the Common Security and Account Agreement.

 

  (k)

Lien Waivers

Receipt by the Intercreditor Agent of: (i) copies of Lien Waivers as have then been (and only to the extent) required pursuant to each Phase 2 Material Construction Contract; (ii) copies of one or more notices of termination of work filed pursuant to the Louisiana Private Works Act in the mortgage records of Plaquemines Parish, Louisiana, certifying termination of the work under the Phase 2 EPC Contract, including the installation, testing and start-up of equipment supplied to the Borrower pursuant to other Phase 2 Material Construction Contracts (other than those Phase 2 Material Construction Contracts referred to in clause (iii) of this Section 14.3(k) (Conditions to Occurrence of Project Phase 2 Completion Date – Lien Waivers)); (iii) copies of one or more notices of termination of work filed pursuant to the Louisiana Private Works Act in the mortgage records of Plaquemines Parish, Louisiana, certifying termination of the work under the Phase 2 Material Construction Contracts described in clauses (e) and (f) of the definition thereof; and (iv) a lien certificate by the recorder of mortgages of Plaquemines Parish, Louisiana, issued after the period for filing a statement of claim or privilege under the Louisiana Private Works Act has expired and confirming that no statements of claim or privilege are of record (other than Permitted Liens).

 

  (l)

Revised Operating Budget

The Intercreditor Agent shall have received the revised Operating Budget relating to the Project required pursuant to Section 10.5 (Operating Budget).

 

  (m)

Senior Facilities Debt Service Reserve Account

The Senior Facilities Debt Service Reserve Account shall have been funded in an amount equal to the Senior Facilities Reserve Amount.

 

-134-

Plaquemines – Amended & Restated Common Terms Agreement


  (n)

Letter of Credit Reimbursement

The Borrower shall have repaid any outstanding LC Reimbursement Payments and/or any LC Loans (as defined in the Credit Facility Agreement) outstanding as a result of a draw on any Letters of Credit.

 

  (o)

Senior Debt/Equity Ratio

The Senior Debt/Equity Ratio shall be no greater than 75:25, as certified by the Borrower.

 

  (p)

Additional Material Project Agreements

The Intercreditor Agent shall have received copies of any Material Project Agreements and required material Permits entered into or issued after the Initial Closing Date, to the extent not previously delivered by the Borrower to the Intercreditor Agent.

 

  14.4

Project Phase 2 Completion Date Waterfall

 

  (a)

Preliminary Determination

The Intercreditor Agent and the Credit Facility Agent shall have received (i) a preliminary determination (together with reasonably detailed calculations therefor) at least 15 Business Days prior to the proposed Project Phase 2 Completion Date and (ii) a final determination (together with reasonably detailed calculations therefor) at least five Business Days prior to the proposed Project Phase 2 Completion Date, in each case, of the amount of the final advance of Term Loans and the payments and transfers to be applied pursuant to Section 14.4(c) (Project Phase 2 Completion Date Waterfall), in each case, in form and substance reasonably satisfactory to the Credit Facility Agent acting in consultation with the Independent Engineer.

 

  (b)

Final Advance of Term Loans

On the day that is one Business Day prior to the Project Phase 2 Completion Date and assuming all conditions to the Project Phase 2 Completion Date have been met or waived as of such day, and the Borrower has given a notice to the Intercreditor Agent requesting such final Advance at least three Business Days prior to such day, the full remaining undrawn amount of the Term Loan Commitment, if any, shall be funded by the Secured Parties holding Term Loan Commitments and deposited into the Construction Account.

 

  (c)

Project Phase 2 Completion Date Waterfall

On the Project Phase 2 Completion Date, (i) amounts on deposit in the Contingency Reserve Account shall be transferred to the Construction Account pursuant to Section 4.5(k)(iv) (Deposits and Withdrawals – Contingency Reserve Account) of the Common Security and Account Agreement, (ii) amounts on deposit in the Phase 2 Pre-Completion Revenues Account shall be

 

-135-

Plaquemines – Amended & Restated Common Terms Agreement


transferred to the Construction Account pursuant to Section 4.5(c)(iii) (Deposits and Withdrawals – Phase 2 Pre-Completion Revenues Account) of the Common Security and Account Agreement and (iii) amounts on deposit in the Construction Account (after giving effect to clauses (i) and (ii) above) shall be applied in the following order of priority:

 

  (A)

first, to pay all outstanding Project Costs that are then due and payable;

 

  (B)

second, to pay all Debt Service then due and payable, if any;

 

  (C)

third, to reserve in the Completion Reserve Account an amount equal to the Permitted Completion Amount;

 

  (D)

fourth, to fund the Senior Facilities Debt Service Reserve Account in an amount equal to the Senior Facilities Reserve Amount (to the extent not funded, at the option of the Borrower, with one or more Acceptable Debt Service Reserve LCs, and taking into account any Acceptable Debt Service Reserve LCs or other cash already on deposit therein);

 

  (E)

fifth, to make a mandatory prepayment in respect of the Term Loans pursuant to Section 3.4(a)(ix) (Mandatory Prepayments – Contingency Reserve Amount) in an amount equal to 100% of the proceeds of any Term Loans that have been funded in respect of the Contingency Reserve Term Loan Commitments; and

 

  (F)

sixth, to the extent any cash remains on deposit in the Construction Account, to make the Project Phase 2 Completion Date Distribution.

 

15.

LOAN FACILITY EVENTS OF DEFAULT

 

  15.1

Loan Facility Events of Default

Except as may be set forth in a Facility Agreement with respect solely to such Facility Agreement, the following events, and no others, shall be Loan Facility Events of Default:

 

  (a)

Payment Default

 

  (i)

The Borrower fails to pay principal amounts due under the Finance Documents; provided that if failure to pay occurs due to a purely administrative error, the Borrower shall have three Business Days to cure such failure; or

 

-136-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

the Borrower fails to pay interest or any other Senior Debt Obligations due under the Finance Documents within three Business Days after those amounts become due.

 

  (b)

Breach of Project Representations and Warranties

 

  (i)

Any representation or warranty made by any Obligor in Article 5 (Representations and Warranties of the Obligors), or any representation, warranty or statement in any certificate, financial statement or other document furnished by any Obligor pursuant to this Agreement, is false when made and if such falsity is capable of being corrected or cured, is not corrected or cured within 60 days after the earlier of (A) the applicable Obligor, becoming aware of such falsity and (B) notice from the Intercreditor Agent to the Borrower, and such falsity or the adverse effects therefrom could reasonably be expected to have a Material Adverse Effect.

 

  (ii)

Any representation or warranty made by the Pledgor in the Security Document referred to in Section 3.3 (Security Interests to be Granted by Pledgor) of the Common Security and Account Agreement is false when made and such falsity is not corrected or cured within 60 days after the earlier of (A) the Borrower becoming aware of such falsity and (B) notice from the Intercreditor Agent to the Borrower, and such falsity or the adverse effects therefrom could reasonably be expected to have a Material Adverse Effect.

 

  (c)

Breach of Certain Covenants

Except as specifically provided for in another Loan Facility Event of Default in this Section 15.1 (Loan Facility Events of Default):

 

  (i)

breach by an Obligor of any covenant described in Article 6 (Incurrence of Additional Senior Debt), Section 7.1(a) (Permitted Development Expenditures), Section 7.2 (Expansion Contracts), Section 8.3 (Amendment of LNG SPAs), Section 9.1 (Change Orders), Section 12.1 (Use of Proceeds), Sections 12.2(a) or (b) (Maintenance of Existence, Franchises, Etc.), Sections 12.5(g) or (k) (Material Project Agreements), Section 12.14 (Limitation on Indebtedness), Section 12.15 (Guarantees), Section 12.16 (Limitation on Liens), Section 12.17 (Sale of Project Property), Section 12.18 (Merger, Division, Liquidation and Sale of All Assets), Section 12.19 (Limitation on Investments and Loans) or Section 12.30 (Margin Regulation);

 

-137-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

breach of Section 12.25 (Historical DSCR) that is not cured within ten Business Days as set forth in Section 12.25 (Historical DSCR);

 

  (iii)

breach by an Obligor of any covenant described in:

 

  (1)

Section 12.2(c) (Maintenance of Existence, Franchises, Etc.);

 

  (2)

Section 12.6 (Compliance with Law);

 

  (3)

Section 12.7 (Environmental Compliance);

 

  (4)

Section 12.5 (Material Project Agreements) clauses (b), (c), (d), (e), or (f) (but excluding covenants therein as they may apply to termination of any LNG SPA); or

 

  (5)

Section 12.13 (Taxes);

in each case with respect to the events in this sub-clause (iii) that is not corrected or cured within 30 days following the earlier of (x) the applicable Obligor becoming aware of such failure and (y) notice from the Intercreditor Agent to the Borrower;

 

  (iv)

material breach by Pledgor of any covenant contained in the Pledge Agreement that is not corrected or cured within 30 days after the earlier of (A) Pledgor becoming aware of such failure; and (B) notice from the Intercreditor Agent to the Borrower and Pledgor;

 

  (v)

(A) breach by an Obligor of:

 

  (1)

Section 12.3 (Project Construction; Maintenance of Properties);

 

  (2)

Section 12.4 (Books and Records; Inspection Rights);

 

  (3)

Section 12.20 (Nature of Business);

 

  (4)

Section 12.27 (Gas Transportation Arrangements; Gas Purchase Arrangements); or

 

  (5)

Section 12.21 (Transactions with Affiliates); or

 

-138-

Plaquemines – Amended & Restated Common Terms Agreement


  (B)

material breach by an Obligor of any other covenant in Article 12 (Obligor Covenants) (except for the covenants

described in Section 12.8 (Permits) and Section 12.10 (FERC Order), which are subject to clause (p) (Loan Facility Events of Default – Permits Generally) below) or any other covenant in this Agreement, the Security Documents, or with respect to any Facility Lender, its Facility Agreement; and

in each case, with respect to the events in this sub-clause (v), that is not corrected or cured within 60 days after the earlier of (1) the applicable Obligor becoming aware of such breach; and (2) notice from the Intercreditor Agent to the Borrower, such cure period to be extended to a total of 90 days so long as the breach is subject to cure, such Obligor is diligently pursuing a cure and such additional cure period could not reasonably be expected to result in a Material Adverse Effect.

 

  (d)

Bankruptcy

(i) a Bankruptcy with respect to an Obligor or the Pledgor has occurred; or

(ii) a Bankruptcy with respect to any Specified Counterparty has occurred.

 

  (e)

Abandonment

Abandonment has occurred and is continuing.

 

  (f)

Destruction

All or substantially all of the Project Facilities is destroyed, lost or damaged.

 

  (g)

Event of Taking

An Event of Taking of (i) all or substantially all of the Project Facilities or (ii) that could reasonably be expected to have a Material Adverse Effect has occurred.

 

  (h)

Security Interests Invalid

Any of the Security Interests over a material portion of the Collateral cease to be validly perfected (subject to applicable Reservations) in favor of the Collateral Agent on behalf of the Secured Parties, and five Business Days have elapsed after the Collateral Agent or Intercreditor Agent gave notice to the Borrower thereof.

 

-139-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

Unsatisfied Judgments

Any one or more of final judgments in excess of $200 million in the aggregate against an Obligor (or against any other Person where an Obligor is liable to satisfy such judgment), in each case such amounts to be measured net of Insurance Proceeds which are reasonably expected to be paid and, in each case, such judgment or judgments remain unpaid, unstayed on appeal, undischarged, unbonded or undismissed for a period of 60 days after the date of entry of such judgment.

 

  (j)

Unenforceability or Termination of Finance Documents

Any of the Finance Documents (other than (x) a Direct Agreement in respect of any LNG SPA that is not a Required LNG SPA then in full force and effect or (y) any Direct Agreement in the case where the occurrence of a Loan Facility Event of Default has been triggered by an event affecting the underlying Material Project Agreement or a Senior Debt prepayment remedy or other Loan Facility Event of Default is applicable under the Finance Documents) or any material provision thereof:

 

  (i)

is expressly repudiated in writing by any party thereto (other than the Collateral Agent, the Account Bank, the Intercreditor Agent or any Facility Lender);

 

  (ii)

shall have been terminated (other than pursuant to the terms thereof following discharge in full of all obligations thereof or otherwise by agreement in writing of the parties thereto not as a result of a Loan Facility Event of Default hereunder); or

 

  (iii)

is declared unenforceable in a final judgment of a court of competent jurisdiction against any party (other than the Collateral Agent, the Account Bank, the Intercreditor Agent or any Facility Lender) and such unenforceability is not cured (subject to any applicable Reservations) within five Business Days following the date of entry of such judgment; provided that such five-Business Day period shall apply only so long as the relevant party is attempting in good faith to cure such unenforceability.

 

  (k)

Unenforceability or Termination of Material Project Agreements:

Any Material Project Agreement or any material provision thereof:

 

  (i)

is expressly repudiated in writing by any party;

 

  (ii)

is declared unenforceable in a final judgment of a court of competent jurisdiction against any party and such unenforceability is not cured (subject to any applicable Reservations) within 60 days following the date of entry of such judgment;

 

-140-

Plaquemines – Amended & Restated Common Terms Agreement


  (iii)

shall have been terminated (other than pursuant to the terms thereof following discharge in full of all obligations thereof or otherwise by agreement in writing of the parties thereto); or

 

  (iv)

shall at any time for any reason cease to be valid and binding or in full force and effect, unless such Material Project Agreement expires or terminates pursuant to its terms;

provided that, in each case of sub-clauses (i) and (ii) above there could reasonably be expected to be a Material Adverse Effect as a result thereof (without regard, for such purpose, to clause (a) of the definition of Material Adverse Effect); provided further that, in respect of sub-clause (ii) above, such 60 day period shall apply only so long as the relevant party is attempting in good faith to cure such unenforceability;

provided further that, in each case of sub-clauses (iii) and (iv) above, any such case shall not give rise to a Loan Facility Event of Default if, (i) in case of any termination of an LNG SPA, the Obligors enter into a Replacement Material Contract within 90 days of such termination, such cure period to be extended to a total of 180 days so long as the breach is subject to cure, such Obligor is diligently pursuing a cure and such additional cure period could not reasonably be expected to result in a Material Adverse Effect and (ii) in case of any termination of any other Material Project Agreement, the Obligors enter into a Replacement Material Contract within 60 days of such termination, such cure period to be extended to a total of 90 days so long as the breach is subject to cure, such Obligor is diligently pursuing a cure and such additional cure period could not reasonably be expected to result in a Material Adverse Effect, in each case in accordance with the requirements of Section 12.5(g) (Material Project Agreements).

 

  (l)

Failure to Achieve Project Completion Date by Date Certain

Either (a) the Project Phase 1 Completion Date does not occur by the Phase 1 LNG Facility Date Certain or (b) the Project Phase 2 Completion Date does not occur by the Phase 2 LNG Facility Date Certain.

 

  (m)

Cross Acceleration (other Indebtedness)

A default has occurred with respect to Indebtedness (other than (i) Indebtedness secured by the Security Documents and (ii) Subordinated Debt) of any Obligor that exceeds a principal amount of $200 million and such default has continued beyond any applicable grace period, and its effect has been to cause the entire amount of such Indebtedness to become due and such Indebtedness remains unpaid or the acceleration of its stated maturity remains unrescinded.

 

-141-

Plaquemines – Amended & Restated Common Terms Agreement


  (n)

Cross Acceleration (Senior Notes)

In respect of any Senior Notes outstanding, if applicable, acceleration of such Senior Notes following an Indenture Event of Default, without prejudice to any Loan Facility Event of Default under clause (a) (Loan Facility Events of Default – Payment Default) above that may be triggered by a breach under any Indenture.

 

  (o)

[Reserved]

 

  (p)

Permits Generally

From and after the Initial Closing Date, any Permit required under Section 12.8 (Permits), Section 12.9 (Export Authorizations) or Section 12.10 (FERC Order) related to the Borrower or the Development is Impaired and such Impairment could reasonably be expected to have a Material Adverse Effect, unless:

 

  (i)

the Borrower provides a reasonable remedial plan (which sets forth in reasonable detail the proposed steps to be taken to cure such Impairment) no later than 30 days following the date that the Borrower has Knowledge of the occurrence of such Impairment;

 

  (ii)

the Borrower diligently pursues the implementation of such remedial plan; and

 

  (iii)

such Impairment is cured no later than 90 days following the occurrence thereof (or such longer period, if any, presented by any administrative, legal, regulatory or statutory time period applicable thereto but only as may be reasonably necessary to cure such Impairment or required by a Governmental Authority; provided that the Borrower shall have no more than 180 days in the aggregate to cure such Impairment).

 

  (q)

ERISA

 

  (i)

On or after the Initial Closing Date, an ERISA Event has occurred and is continuing and such event, whether individually or in the aggregate, could reasonably be expected to result in a Material Adverse Effect; or

 

-142-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

the aggregate “amount of unfunded benefit liabilities” (within the meaning of Section 4001(a)(18) of ERISA) under all Plans determined in accordance with Title IV of ERISA could reasonably be expected to result in a Material Adverse Effect.

 

  (r)

Change of Control

A Change of Control has occurred and is continuing.

 

  15.2

Declaration of Loan Facility Declared Default

 

  (a)

A Loan Facility Declared Default occurs upon delivery to the Borrower (with a copy to the Collateral Agent), after any applicable grace or cure period has expired, of a certificate from the Intercreditor Agent stating that any Loan Facility Event of Default has occurred and is Continuing and declaring a Loan Facility Declared Default.

 

  (b)

A Loan Facility Declared Default also shall be deemed to have occurred and been declared without the delivery of such a certificate or such declaration or any other notice upon the occurrence of a Loan Facility Event of Default referred to in Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy).

 

  15.3

Cessation of Loan Facility Declared Default

The Intercreditor Agent shall promptly notify the Collateral Agent, the Borrower and each Facility Lender upon learning of the cessation of the Loan Facility Event of Default to which such certificate(s) related (such notice, a “Cessation Notice”). Upon delivery of a Cessation Notice, the applicable Loan Facility Declared Default shall be deemed not to be Continuing.

 

  15.4

Instruction to Intercreditor Agent

Any Senior Creditor Group Representative may deliver an instruction to the Intercreditor Agent to deliver a certificate stating that any Loan Facility Event of Default has occurred and Requisite Intercreditor Parties may deliver an instruction to the Intercreditor Agent to deliver a Cessation Notice; provided that in the case of a Loan Facility Event of Default that arises solely under an individual Facility Agreement, such instruction to declare a Loan Facility Event of Default or a cessation of a Loan Facility Event of Default to the Intercreditor Agent may be given only by the Senior Creditor Group Representative representing the Facility Lenders under such Facility Agreement (and not any other Senior Creditor Group Representatives).

 

-143-

Plaquemines – Amended & Restated Common Terms Agreement


16.

COMMON REMEDIES AND ENFORCEMENT

 

  16.1

Facility Lender Remedies for Loan Facility Declared Events of Default

 

  (a)

Enforcement Action

Subject to clause (b) (Facility Lender Remedies for Loan Facility Declared Events of Default – Initiating Percentage for Enforcement Action with Respect to Collateral) below and the Common Security and Account Agreement, upon the occurrence and Continuation of a Loan Facility Declared Default, based on the instruction procedures described in clause (b) (Facility Lender Remedies for Loan Facility Declared Events of Default – Initiating Percentage for Enforcement Action with Respect to Collateral) below, rights and remedies (each, an “Enforcement Action”) may be exercised on behalf of the Facility Lenders under their Facility Agreement, including the following:

 

  (i)

suspension of undrawn Facility Debt Commitments under the Facility Agreements;

 

  (ii)

termination of undrawn Facility Debt Commitments and acceleration of all Senior Debt Obligations under the Facility Agreements;

 

  (iii)

directing the Collateral Agent to take control of the Secured Accounts and apply the balances in accordance with Section 4.7 (Cash Waterfall) of the Common Security and Account Agreement;

 

  (iv)

[reserved]; and

 

  (v)

subject to clause (b) (Facility Lender Remedies for Loan Facility Declared Events of Default – Initiating Percentage for Enforcement Action with Respect to Collateral) below, requesting the Collateral Agent to exercise all rights with respect to the Security Interests and apply the proceeds from the enforcement of Security Interests.

 

  (b)

Initiating Percentage for Enforcement Action with Respect to Collateral

Upon a Loan Facility Declared Default, the Required Intercreditor Parties shall have the right to instruct the Intercreditor Agent who shall in turn request the Collateral Agent (and confirm in writing to the Collateral Agent that such instruction has been given pursuant to this Agreement and Intercreditor Agreement) to take Enforcement Action pursuant to the Common Security and Account Agreement; provided that upon an Event of Default under Section 15.1(d) (Loan Facility Events of Default – Bankruptcy), all Senior Debt Obligations under Loans shall be accelerated automatically and shall immediately become due and payable, without presentment, demand, protest or other notice or action of any kind, all of which are expressly waived by the Obligors.

 

-144-

Plaquemines – Amended & Restated Common Terms Agreement


  16.2

Remedies for Events of Default under Facility Agreements

At any time after the occurrence of any Loan Facility Event of Default that is not listed in Section 15.1 (Loan Facility Events of Default) of this Agreement but arises only under an individual Facility Agreement, the relevant Facility Agent may, subject to the terms and conditions of this Agreement, the Common Security and Account Agreement and the Intercreditor Agreement, exercise the express remedies available to it in accordance with such Facility Agreement and shall promptly notify each other Facility Agent, the Borrower and the Intercreditor Agent thereof.

 

  16.3

Permitted Actions under Common Security and Account Agreement

Nothing in this Article 16 (Common Remedies and Enforcement) shall limit or restrict any right of any Secured Party or the Collateral Agent pursuant to Section 6.3 (Conduct of Security Enforcement Action) of the Common Security and Account Agreement.

 

17.

INTERCREDITOR ARRANGEMENTS

 

  17.1

Facility Agents; Facility Lender Action

 

  (a)

Each of the Facility Agents hereby represents that it has been duly appointed pursuant to the applicable Facility Agreement to represent the applicable Facility Lender(s) that is a lender or are lenders under such Facility Agreement and is entitled to vote and give instructions to the Intercreditor Agent (and, where applicable, to act thereunder) on behalf of the Facility Lender(s) that is a lender or are lenders under such Facility Agreement.

 

  (b)

Each Facility Agent shall, for purposes of this Agreement, act in its capacity as “Facility Agent” under the applicable Facility Agreement and shall, for purposes of the Common Security and Account Agreement, act in the capacity of Senior Creditor Group Representative on behalf of the Facility Lender(s) that is a lender or are lenders under the applicable Facility Agreement (each such group of Facility Lender(s) under an individual Facility Agreement being a “Senior Creditor Group” for purposes of the Common Security and Account Agreement).

 

  (c)

Notwithstanding anything herein to the contrary, where any Facility Agent exercises any right or discretion, makes any Decision or determination or performs any obligation under this Agreement, references to “Facility Agent” in such circumstances shall mean “Facility Agent acting pursuant to instructions from its Facility Lender(s) in accordance with the Intercreditor Agreement or the applicable Facility Agreement, as the case may be.”

 

-145-

Plaquemines – Amended & Restated Common Terms Agreement


  (d)

Notwithstanding anything herein to the contrary, where:

 

  (i)

the Intercreditor Agent exercises any right or discretion, makes any Decision or determination or performs any obligation under this Agreement, references to “Intercreditor Agent” in such circumstances shall mean “Intercreditor Agent acting pursuant to instructions from Requisite Intercreditor Parties as may be required in accordance with the Intercreditor Agreement”; and

 

  (ii)

a Facility Agent, in its capacity as such or as a Senior Creditor Group Representative, makes any Decision or determination or performs any obligation under this Agreement, references to “Facility Agent” and “Senior Creditor Group Representative” in such circumstances shall mean such “Facility Agent” or “Senior Creditor Group Representative”, in each case acting pursuant to instructions from requisite Facility Lenders as may be required in accordance with its Facility Agreement and, if applicable, the Intercreditor Agreement.

 

  17.2

Agreement to Comply with Intercreditor Agreement

The Intercreditor Agent agrees for the benefit of the Borrower that, in discharging its duties as Intercreditor Agent, it shall act at all times in accordance with the terms of the Intercreditor Agreement and the Common Security and Account Agreement as they may be amended from time to time, and which shall include, for the avoidance of doubt, the obtaining of the consent of the Borrower to any replacement Intercreditor Agent to the extent required herein or therein.

 

  17.3

Agreement Not to Amend Entrenched Intercreditor Provisions

The Intercreditor Agent and the Facility Agents agree not to Modify the following provisions of the Intercreditor Agreement unless otherwise agreed in writing by the Borrower (in the addition to the agreement of any other party that is required under the Intercreditor Agreement):

 

  (a)

Article 1 (Definitions and Interpretation);

 

  (b)

Section 2.2 (Intercreditor Agent’s Rights and Obligations);

 

  (c)

Section 2.4(d) (Defaults);

 

  (d)

Sections 2.7(a) and (b) (Resignation of Intercreditor Agent);

 

  (e)

Section 2.8 (Removal of Intercreditor Agent);

 

-146-

Plaquemines – Amended & Restated Common Terms Agreement


  (f)

Section 3.1 (Decision Making);

 

  (g)

Section 3.2 (Voting Generally: Intercreditor Party Decisions and Intercreditor Votes);

 

  (h)

Section 3.3 (Intercreditor Votes: Each Party’s Entitlement to Vote);

 

  (i)

Section 3.4 (Casting of Votes);

 

  (j)

Section 3.6 (Other Voting Considerations);

 

  (k)

Section 3.7 (Voting by Hedging Banks);

 

  (l)

Section 3.8 (Voting by Sponsor and its Affiliates);

 

  (m)

Section 4.1 (100% Voting Issues);

 

  (n)

Section 4.2 (Special Voting Issues);

 

  (o)

Section 4.3 (Majority Voting Issues);

 

  (p)

Section 4.4 (Administrative Decisions);

 

  (q)

Section 4.6 (Individual Senior Creditor Group Decisions);

 

  (r)

Article 5 (Agreement of Hedging Banks);

 

  (s)

Section 6.1 (Governing Law);

 

  (t)

Section 7.2 (Amendment);

 

  (u)

Section 7.12 (Third-party Beneficiaries);

 

  (v)

Schedule 1 (All Loan Facilities Decisions); and

 

  (w)

Schedule 2 (Administrative Decisions).

 

18.

THE INTERCREDITOR AGENT

 

  18.1

Intercreditor Agreement

Pursuant to and in accordance with the Intercreditor Agreement, the Facility Lenders have appointed the Intercreditor Agent to, among other things, act as their agent under and in connection with this Agreement and the Intercreditor Agreement and any other Finance Document to which the Intercreditor Agent (in such capacity) is a party.

 

-147-

Plaquemines – Amended & Restated Common Terms Agreement


  18.2

Relationship

 

  (a)

The Intercreditor Agent shall in no respect be the agent of the Borrower by virtue of this Agreement.

 

  (b)

The Intercreditor Agent shall not be liable to the Borrower for any breach by any Person (other than for the Intercreditor Agent’s own gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final and non-appealable judgment), or be liable to any Person for any breach by the Borrower, of this Agreement or any of the Finance Documents.

 

  18.3

Delivery of Documentation

Executed counterparts of each of the Finance Documents have been delivered to the Intercreditor Agent on, or prior to, the Upsize Closing Date and the Intercreditor Agent has acknowledged receipt thereof. Each of the Parties hereto agrees to deliver to the Intercreditor Agent executed counterparts of any Permitted Hedging Instrument or any Senior Debt Instrument relating to Replacement Debt, Working Capital Debt and of any instrument amending or modifying any agreement previously delivered to the Intercreditor Agent.

 

  18.4

Liability

The Intercreditor Agent shall not be responsible to the Borrower for:

 

  (a)

the execution (other than its own execution), genuineness, validity, adequacy, enforceability, admissibility in evidence or sufficiency of any Finance Document or any other document;

 

  (b)

the collectability of amounts payable under any Finance Document; and

 

  (c)

the adequacy, accuracy and/or completeness of any statements (whether written or oral) made in, or in connection with, any Finance Document, with the exception of any statements made with respect to itself.

 

  18.5

Exoneration

 

  (a)

Without limiting clause (b) of this Section 18.5 below, the Intercreditor Agent (including its officers, employees, agents and attorneys) shall not be liable to the Borrower for any action taken or not taken by it under, or in connection with, this Agreement or any other Finance Document unless directly caused by its gross negligence, fraud or willful misconduct as determined by a final non-appealable judgment of a court of competent jurisdiction.

 

-148-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

The Borrower may not bring any proceedings against any officer, employee, agent or attorney of the Intercreditor Agent in respect of any claim it might have against it or in respect of any act or omission of any kind (including gross negligence, fraud or willful misconduct) by that officer, employee or agent in relation to this Agreement or any other Finance Document. Without prejudice to the provisions of the preceding sentence of this clause (b), the restriction against taking proceedings set out in the preceding sentence of this clause (b) is not and shall not be construed as a waiver of any claim based on the conduct of such officer, employee or agent.

 

  18.6

Reliance

 

  (a)

The Intercreditor Agent shall be entitled to rely conclusively on the list of authorized signatories of the Obligors delivered to it pursuant to Section 4.2(k) (Conditions to Upsize Closing Date – Bank Regulatory Requirements) (with such written updates to such authorized signatories (certifying the names and true signatures of any new authorized signatories) as may be notified by the Obligors to the Intercreditor Agent from time to time).

 

  (b)

The Facility Lenders shall communicate to the Intercreditor Agent only through the relevant Facility Agent.

 

  18.7

Resignation and Succession

 

  (a)

The Borrower acknowledges that, subject to and in accordance with the terms and conditions of the Intercreditor Agreement, the Intercreditor Agent may resign and a successor Intercreditor Agent shall be appointed in accordance with the terms of the Intercreditor Agreement.

 

  (b)

The resignation of the Intercreditor Agent and the appointment of any successor in that capacity shall both become effective only upon the satisfaction of the applicable conditions set out in the Intercreditor Agreement. On satisfaction of such conditions, the successor Intercreditor Agent shall succeed to the position of the Intercreditor Agent under this Agreement and the term “Intercreditor Agent” shall include the successor Intercreditor Agent.

 

  (c)

Upon its resignation becoming effective, Section 18.5(a) (Exoneration) and this Section 18.7 (Resignation and Succession) shall continue to benefit a retiring Intercreditor Agent in respect of any action taken or not taken by it under or in connection with this Agreement and the other Finance Documents while it was an Intercreditor Agent, and it shall have no further obligations under this Agreement and the other Finance Documents.

 

-149-

Plaquemines – Amended & Restated Common Terms Agreement


19.

CHANGES TO THE PARTIES

 

  19.1

Represented Parties; Successors and Assigns

Each Facility Agent represents that it is authorized on behalf of itself and on behalf of each Facility Lender under its Facility Agreement to enter into this Agreement. This Agreement is binding on the successors, permitted transferees and assigns of each Party.

 

  19.2

Transfers by the Obligors

The Obligors may not assign or transfer any of their rights or obligations under this Agreement without the prior written consent of the Intercreditor Agent, and any such attempted assignment or transfer without such prior written consent shall be void and invalid.

 

  19.3

Replacement of Facility Agents

 

  (a)

Any Facility Agent may be replaced by the Facility Lender(s) under the relevant Facility Agreement in accordance with the terms of such Facility Agreement, pursuant to which such Facility Agent was appointed and the Borrower, the Intercreditor Agent and each other Facility Agent shall be notified in writing promptly of any such replacement.

 

  (b)

No replacement Facility Agent shall become a Facility Agent under this Agreement unless and until:

 

  (i)

the resignation in writing of the Facility Agent being replaced has been delivered to the Borrower, the Intercreditor Agent and each other Facility Agent;

 

  (ii)

a “Replacement Facility Agent Accession Agreement” substantially in the form set forth in Schedule P – 1 (Replacement Facility Agent Accession Agreement) has been executed and delivered to the Intercreditor Agent; and

 

  (iii)

such Replacement Facility Agent Accession Agreement, when delivered to the Intercreditor Agent, is accompanied by one or more certificates as to the due authorization, execution and delivery of the Replacement Facility Agent Accession Agreement and incumbency of the officers or attorneys-in-fact who executed the Replacement Facility Agent Accession Agreement.

 

  (c)

The Intercreditor Agent shall, as soon as reasonably practicable, after receiving (A) a duly completed and executed Replacement Facility Agent Accession Agreement which appears on its face to comply with the terms of this Agreement; and (B) all of the documents required to be delivered to it pursuant to this Section 19.3 (Replacement of Facility Agents):

 

-150-

Plaquemines – Amended & Restated Common Terms Agreement


  (i)

countersign such Replacement Facility Agent Accession Agreement by way of acceptance thereof; and

 

  (ii)

deliver to the Borrower and each Facility Agent the notice referred to in Section 8 (Effective Date) of such Replacement Facility Agent Accession Agreement.

 

  (d)

Upon the Intercreditor Agent delivering to the Borrower and each Facility Agent the notice referred to in Section 8 (Effective Date) of such Replacement Facility Agent Accession Agreement, the Facility Agent shall become (if not already) a party to this Agreement.

 

  19.4

Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement

 

  (a)

If the Borrower incurs, pursuant to this Agreement, Additional Senior Debt permitted by and in accordance with Article 6 (Incurrence of Additional Senior Debt), then each Facility Agent in respect of such Additional Senior Debt to be appointed pursuant to the applicable Facility Agreement(s) shall accede to this Agreement on behalf of itself and on behalf of the Facility Lenders under the Facility Agreement in respect of which the Additional Senior Debt is incurred.

 

  (b)

No Facility Agent to be appointed pursuant to Facility Agreements in respect of Additional Senior Debt shall become a Facility Agent under this Agreement, and therefore no Facility Lender under a Facility Agreement in respect of Additional Senior Debt incurred pursuant to this Agreement shall become a Facility Lender under this Agreement, unless and until:

 

  (i)

a “New Facility Agent Accession Agreement (Additional Senior Debt)” substantially in the form set forth in Schedule P – 2 (New Facility Agent Accession Agreement (Additional Senior Debt)) shall have been executed and delivered to the Intercreditor Agent, in which, among the other provisions set forth in such New Facility Agent Accession Agreement (Additional Senior Debt), the relevant Facility Agent agrees (i) on behalf of itself to become a party to this Agreement and to represent the Facility Lenders under the relevant Facility Agreement and to be bound by all of the terms and conditions of this Agreement and (ii) on behalf of the Facility Lenders under the Facility Agreement in respect of which the Additional Senior Debt is incurred, to become a party to this Agreement and to be bound by all of the terms and conditions of this Agreement; and

 

-151-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

such New Facility Agent Accession Agreement (Additional Senior Debt), when delivered to the Intercreditor Agent, shall have been accompanied by one or more certificates as to the due authorization, execution and delivery of the New Facility Agent Accession Agreement (Additional Senior Debt) and incumbency of the officers or attorneys-in-fact who executed the New Facility Agent Accession Agreement (Additional Senior Debt).

 

  (c)

The Facility Agent representing the Facility Lenders providing the Additional Senior Debt referred to in this Section 19.4 (Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement) shall, concurrently with acceding to this Agreement pursuant to this Section 19.4 (Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement), accede to (A) the Common Security and Account Agreement in accordance with Section 2.2 (Incremental Senior Debt) of the Common Security and Account Agreement and (B) the Intercreditor Agreement.

 

  (d)

A copy of the related Facility Agreements shall be attached to the New Facility Agent Accession Agreement (Additional Senior Debt) as an exhibit.

 

  (e)

The Intercreditor Agent shall, as soon as reasonably practicable, after receiving (A) a duly completed and executed New Facility Agent Accession Agreement (Additional Senior Debt) which appears on its face to comply with the terms of this Agreement and the Intercreditor Agreement; and (B) all of the documents required to be delivered to it pursuant to this Section 19.4 (Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement):

 

  (i)

countersign such New Facility Agent Accession Agreement (Additional Senior Debt) by way of acceptance thereof; and

 

  (ii)

deliver to the Borrower and each Facility Agent the notice referred to in Section 8 (Effective Date) of such New Facility Agent Accession Agreement (Additional Senior Debt) (if applicable).

 

  (f)

Upon the Intercreditor Agent delivering to the Borrower and each Facility Agent the notice referred to in Section 8 (Effective Date) of such New Facility Agent Accession Agreement (Additional Senior Debt), the Facility Agent on its own behalf and on behalf of the Facility Lenders under its Facility Agreement shall become party to this Agreement in such capacity.

 

-152-

Plaquemines – Amended & Restated Common Terms Agreement


19.5

Mitigation Obligations; Replacement of Lenders

 

  (a)

If any Facility Lender requires the Borrower to pay any Indemnified Taxes or additional amounts to any Facility Lender or any Governmental Authority for the account of any Facility Lender pursuant to Article 21 (Tax Gross-Up and Indemnities) or requests compensation under Section 22.1 (Increased Costs), then such Facility Lender (at the request of the Borrower) shall use commercially reasonable efforts to designate a different lending office for funding or booking its Loans under the Finance Documents or to assign its rights and obligations hereunder to another of its offices, branches or Affiliates or take any other reasonable steps not inconsistent with any applicable legal or regulatory restrictions or the internal policies of such Facility Lender that it would otherwise take in similar circumstances under comparable provisions of other financing agreements if, in the reasonable judgment of such Facility Lender, such designation or assignment (i) would eliminate or reduce amounts payable pursuant to Article 21 (Tax Gross-Up and Indemnities) or Section 22.1 (Increased Costs), as applicable, in the future, and (ii) would not subject such Facility Lender to any unreimbursed cost or expense and would not otherwise, in the reasonable opinion of such Facility Lender, be disadvantageous or prejudicial to such Facility Lender. The Borrower hereby agrees to pay and/or indemnify any Facility Lender for all reasonable costs and expenses incurred by such Facility Lender in connection with any such designation or assignment.

 

  (b)

If any Facility Lender reasonably determines that any Change in Law has made it unlawful, or if any Governmental Authority has asserted, with respect to any Initial Senior Creditor, after the Initial Closing Date and, with respect to any Incremental Senior Creditor, after the Upsize Closing Date that it is unlawful, for such Facility Lender or its applicable lending office to fund or maintain its Loans, including, in the case of any Facility Lender under the Credit Facility Agreement, the delivery of an Illegality Notice pursuant to Section 5.01 (Illegality) of the Credit Facility Agreement (an “Illegality Event”), such Facility Lender shall, in good faith consultation with the Borrower, take all reasonable steps to mitigate any circumstances which arise and which would result in any amount becoming payable under or pursuant to, or cancelled pursuant to, Section 3.4(a)(vi) (Mandatory Prepayments Illegality), including transferring its rights and obligations under the Finance Documents to another Affiliate or lending office and, to the extent applicable, converting its outstanding Loans as permitted under the relevant Facility Agreement; provided that this clause (b) in no way limits the obligations of the Borrower under any of the Finance Documents. If, notwithstanding its obligations under this clause (b), such Facility Lender is unable to fund or maintain its Loans as a result of such Illegality Event, the Facility Lender shall promptly notify its Facility Agent upon becoming aware of that Illegality Event, which notice shall set forth in reasonable detail all relevant information about such Illegality Event, and such Facility Agent shall promptly notify and provide such information to the Intercreditor Agent, who shall forward such notice to the Borrower.

 

-153-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

Subject to clause (d) below, if:

 

  (i)

(A) the Borrower is required to pay any Indemnified Taxes or additional amounts to any Facility Lender or any Governmental Authority for the account of any Facility Lender pursuant to clause (a) above or (B) any Facility Lender requests compensation under clause (a) above, and, in each case, such Facility Lender has declined or is unable to designate a different lending office or assign its rights and obligations to another of its offices, branches or Affiliates or take any other reasonable steps in accordance with clause (a) above;

 

  (ii)

any Facility Lender notifies the Borrower of an Illegality Event pursuant to clause (b) above;

 

  (iii)

any Facility Lender becomes a Defaulting Lender; or

 

  (iv)

any Facility Lender becomes a Non-Consenting Lender,

then the Borrower may, at its sole expense and effort, upon notice to such Facility Lender and its Facility Agent as provided herein, require such Facility Lender to assign and delegate, without recourse (in accordance with and subject to the restrictions contained in, and consents required by the applicable Facility Agreement), all of its interests, rights (other than its existing rights to payments pursuant to Article 21 (Tax Gross-Up and Indemnities) or Section 22.1 (Increased Costs), as applicable) and obligations under the applicable Facility Agreement and the related Finance Documents to an Acceptable Lender that shall assume such obligations (which assignee may be another Facility Lender, if a Facility Lender accepts such assignment); provided that:

 

  (I)

such Facility Lender shall have received payment of an amount equal to the Senior Debt Obligations due and payable to such Facility Lender at the time from such assignee (to the extent of such outstanding principal and accrued interest and fees) or the Borrower (in the case of all other amounts);

 

  (II)

in the case any such assignment resulting from a claim for indemnification under Article 21 (Tax Gross-Up and Indemnities), such assignment shall result in a reduction in such payment of Indemnified Taxes or additional amounts to any Facility Lender or any Governmental Authority for the account of any Facility Lender thereafter;

 

-154-

Plaquemines – Amended & Restated Common Terms Agreement


  (III)

in the case of any such assignment resulting from a claim for compensation under Section 22.1 (Increased Costs), such assignment will result in a reduction in such compensation thereafter;

 

  (IV)

such assignment may be made on a non pro rata basis to existing or non-affected Facility Lenders but otherwise subject to Section 3.6 (Prepayment Fees and Funding Losses) and the transfers terms of the applicable Facility Agreement;

 

  (V)

such assignment does not conflict with applicable law or regulations;

 

  (VI)

in the case of any assignment resulting from a Facility Lender becoming a Non-Consenting Lender, the applicable assignee shall have consented to the applicable amendment, waiver or consent; and

 

  (VII)

the Borrower shall have paid to the Facility Agent the assignment fee (if any).

 

  (d)

A Facility Lender shall not be required to make any such assignment or delegation pursuant to clause (c) above if, prior thereto, as a result of a waiver by such Facility Lender or otherwise, the circumstances entitling the Borrower to require such assignment and delegation pursuant to clause (c) above cease to apply. Notwithstanding the satisfaction of each of the conditions set forth in Article 21 (Tax Gross-Up and Indemnities) or Section 22.1 (Increased Costs), a Facility Lender shall have the right to refuse to be replaced pursuant to sub-clause 19.5(c)(i) above; provided that the Borrower shall no longer be obligated to pay such Facility Lender any of the compensation or additional amounts incurred or accrued under Article 21 (Tax Gross-Up and Indemnities) or Section 22.1 (Increased Costs) from and after the date that such replacement would have occurred but for such Facility Lender’s refusal.

 

  (e)

As a condition of the right of the Borrower to remove any Facility Lender pursuant to this Section 19.5 (Mitigation Obligations; Replacement of Lenders), the Borrower shall either:

 

  (i)

arrange for the assignment or novation of any Permitted Hedging Instruments with such Facility Lender or any of its Affiliates simultaneously with such removal; or

 

-155-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

terminate the applicable Permitted Hedging Instruments and pay any relevant Hedging Termination Amount.

 

19.6

Transfers by a Facility Lender

Facility Lenders with rights or obligations under this Agreement or any other Finance Documents to which it is a party (in its capacity as a Facility Lender) (an “Existing Facility Lender”) may not assign or transfer, novate or otherwise dispose of any of their rights or obligations in existence at such time except in accordance with the relevant Facility Agreement, and any attempted assignment or transfer without complying with the provisions of this Section 19.6 (Transfers by a Facility Lender) shall be void and invalid.

 

19.7

Register

The Facility Agent under each Facility Agreement shall maintain a register of Lenders under such Facility Agreement in accordance with the terms and conditions of the relevant Facility Agreement (the “Register”).

 

19.8

Resulting Increased Costs

If:

 

  (a)

any assignment or transfer of all or any part of the rights and/or obligations of a Facility Lender pursuant to this Agreement and the applicable Facility Agreement; or

 

  (b)

any change in a Facility Lender’s facility office from that described in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement,

would, but for this Section 19.8 (Resulting Increased Costs), result, as a consequence of circumstances which are prevailing at that time, in the Borrower being obliged to pay any incurred costs (whether as a result of increased costs, illegality or fees in respect of Security Documents, Direct Agreements or perfection of security interests or similar provisions, except as a result of the tax gross-ups provided for under Article 21 (Tax Gross-Up and Indemnities)) or indemnities which would not have been payable if such assignment, novation, transfer or change of office had not occurred, then, unless such assignment, novation, transfer or change in facility office was made at the request of the Borrower in accordance with mitigation provisions of the Finance Documents, the Facility Lender shall only be entitled to receive those amounts to the extent that such amounts would have been payable in connection with the Existing Facility Lender or the Existing Facility Lender’s facility office had the assignment, transfer or change in facility office not occurred.

 

-156-

Plaquemines – Amended & Restated Common Terms Agreement


20.

SUBORDINATION

 

  20.1

Subordination

 

  (a)

The Parties hereto agree that to the extent that the Sponsor or any Affiliate thereof, or any other Person intends to provide Subordinated Debt to the Obligors after the Upsize Closing Date, each Obligor shall require that the Sponsor, such Affiliate or other Person, as applicable, lending it such Subordinated Debt shall enter into as a condition precedent to providing such Subordinated Debt a Subordination Agreement substantially in the form included in Schedule S – 1 (Form of General Subordination Agreement) hereto.

 

  (b)

The Parties hereto agree that on the Initial Closing Date the Obligors entered into a subordination agreement substantially in the form included in Schedule S – 2 (Form of Obligor Subordination Agreement) hereto, which shall apply to any Indebtedness any Obligor may from time to time be owed by any other Obligor.

 

21.

TAX GROSS-UP AND INDEMNITIES

 

  21.1

Withholding Tax Gross-Up

Any and all payments by or on account of any obligation of the Borrower under or in connection with any Finance Document shall be made without deduction or withholding for or on account of any Taxes, except as required by applicable law. If any applicable law (as determined in the good faith discretion of the Borrower or the relevant Facility Agent, as applicable) requires the deduction or withholding of any Tax from any such payment by the Borrower or the applicable Facility Agent, then the Borrower or the applicable Facility Agent shall make such deduction or withholding and shall timely pay the full amount deducted or withheld to the relevant Governmental Authority in accordance with applicable law and, if such Tax is an Indemnified Tax, then the sum payable by the Borrower shall be increased as necessary so that after such deduction or withholding has been made (including such deductions and withholdings applicable to additional sums payable under this Article 21 (Tax Gross-Up and Indemnities)), the relevant Finance Party receives an amount equal to the sum it would have received had no such deduction or withholding of Indemnified Taxes been made.

 

-157-

Plaquemines – Amended & Restated Common Terms Agreement


  21.2

Payment of Other Taxes

Without duplication of Section 21.1 (Withholding Tax Gross-Up) and Section 21.3 (Indemnification by the Borrower), the Borrower shall timely pay to the relevant Governmental Authority in accordance with applicable law, or at the option of the applicable Facility Agent timely reimburse it for the payment of, any Other Taxes.

 

  21.3

Indemnification by the Borrower

Without duplication of Section 21.1 (Withholding Tax Gross-Up) and Section 21.2 (Payment of Other Taxes), the Borrower shall indemnify each Finance Party and each Facility Agent (and any of their respective Affiliates), within 20 Business Days after written demand therefor, for the full amount of any Indemnified Taxes (including Indemnified Taxes imposed or asserted on or attributable to amounts payable under this Article 21 (Tax Gross-Up and Indemnities)) payable or paid by, or required to be withheld or deducted from a payment to, such Finance Party or Facility Agent (or Affiliate) in connection with a Finance Document, and any reasonable expenses arising therefrom or with respect thereto (but excluding any such amounts resulting from the gross negligence, bad faith or willful misconduct of such Finance Party or Facility Agent (or Affiliate) as determined by a final non- appealable judgment in a court of competent jurisdiction), whether or not such Indemnified Taxes were correctly or legally imposed or asserted by the relevant Governmental Authority. A certificate setting forth in reasonable detail the basis for such claim and the calculation of the amount of any such payment or liability delivered to the Borrower by a Finance Party (with a copy to the relevant Facility Agent), or by a Facility Agent on its own behalf or on behalf of a Finance Party, shall be conclusive absent manifest error.

 

  21.4

Indemnification by the Facility Lenders

Each Facility Lender shall severally indemnify its Facility Agent, within 20 Business Days after written demand therefor, for (a) any Indemnified Taxes attributable to such Facility Lender (but only to the extent that the Borrower has not already indemnified such Facility Agent for such Indemnified Taxes and without limiting the obligation of the Borrower to do so), (b) any Taxes attributable to such Facility Lender’s failure to comply with the provisions of Section 19.6 (Transfers by a Facility Lender) and the relevant Facility Agreement relating to the maintenance of a Participant Register and (c) any Excluded Taxes attributable to such Facility Lender, in each case, that are payable or paid by such Facility Agent in connection with any Finance Document, and any reasonable expenses arising therefrom or with respect thereto, whether or not such Taxes were correctly or legally imposed or asserted by the relevant Governmental Authority. A certificate as to the amount of such payment or liability delivered to any Facility Lender by its Facility Agent shall be conclusive absent manifest error. Each Facility Lender hereby authorizes its Facility Agent to set off and apply any and all amounts at any time owing to such Facility Lender under any Finance Document or otherwise payable by such Facility Agent to the Facility Lender from any other source against any amount due to such Facility Agent under this Section 21.4 (Indemnification by the Facility Lenders).

 

-158-

Plaquemines – Amended & Restated Common Terms Agreement


  21.5

Status of Facility Lenders and Facility Agents

 

  (a)

Any Facility Lender entitled to an exemption from or reduction of withholding Tax with respect to payments made under any Finance Document shall deliver to the Borrower and its Facility Agent, at the time or times reasonably requested by the Borrower or such Facility Agent, such properly completed and executed documentation reasonably requested by the Borrower or such Facility Agent as shall permit such payments to be made without withholding or at a reduced rate of withholding. In addition, any Facility Lender, if reasonably requested by the Borrower or such Facility Agent, shall deliver such other documentation prescribed by applicable law or reasonably requested by the Borrower or such Facility Agent as shall enable the Borrower or such Facility Agent to determine whether or not such Facility Lender is subject to backup withholding or information reporting requirements. Notwithstanding anything to the contrary in the preceding two sentences, the completion, execution and submission of such documentation (other than such documentation set forth in sub-clauses 21.5(b)(i), 21.5(b)(ii) and 21.5(b)(iv) below) shall not be required if, in the Facility Lender’s reasonable judgment, such completion, execution or submission would subject such Facility Lender to any material unreimbursed cost or expense or would materially prejudice the legal or commercial position of such Facility Lender.

 

  (b)

Without limiting the generality of the foregoing:

 

  (i)

any Facility Lender that is a US Person shall deliver to the Borrower and its Facility Agent on or prior to the date on which such Facility Lender becomes a Facility Lender under the relevant Facility Agreement (and from time to time thereafter upon the reasonable request of the Borrower or such Facility Agent) two executed copies of IRS Form W-9 certifying that such Facility Lender is exempt from US federal backup withholding tax;

 

  (ii)

any Facility Lender that is not a US Person shall, to the extent it is legally entitled to do so, deliver to the Borrower and its Facility Agent (in such number of copies as shall be requested by the recipient) on or prior to the date on which such Facility Lender becomes a Facility Lender under the relevant Facility Agreement (and from time to time thereafter upon the reasonable request of the

 

-159-

Plaquemines – Amended & Restated Common Terms Agreement


  Borrower or such Facility Agent) whichever of the following is applicable:

 

  (A)

in the case of a Facility Lender claiming the benefits of an income tax treaty to which the United States is a party (x) with respect to payments of interest under any Finance Document, executed copies of IRS Form W-8BEN or IRS Form W-8BEN-E (or any successor form) establishing an exemption from, or reduction of, US federal withholding Tax pursuant to the “interest” article of such tax treaty and (y) with respect to any other applicable payments under any Finance Document, IRS Form W-8BEN or IRS Form W- 8BEN-E (or any successor form) establishing an exemption from, or reduction of, US federal withholding Tax pursuant to the “business profits” or “other income” article of such tax treaty;

 

  (B)

executed copies of IRS Form W-8ECI (or any successor form);

 

  (C)

in the case of a Facility Lender claiming the benefits of the exemption for portfolio interest under Section 881(c) of the Code, (x) a certificate to the effect that such Facility Lender is not a “bank” within the meaning of Section 881(c)(3)(A) of the Code, a “10 percent shareholder” of the Borrower (or, if the Borrower is a disregarded entity for U.S. federal income tax purposes, of its first regarded owner) within the meaning of Section 881(c)(3)(B) of the Code, or a “controlled foreign corporation” described in Section 881(c)(3)(C) of the Code (a “US Tax Compliance Certificate”) and (y) executed copies of IRS Form W-8BEN or IRS Form W-8BEN-E (or any successor form); or

 

  (D)

to the extent a Facility Lender is not the beneficial owner, executed copies of IRS Form W-8IMY, accompanied by IRS Form W-8EXP, IRS Form W-8ECI, IRS Form W-8BEN or IRS Form W-8BEN-E, a US Tax Compliance Certificate, IRS Form W-9 (or, in each case, any successor form), and/or other certification documents from each beneficial owner, as applicable; provided that if the Facility Lender is a partnership and one or more direct or indirect partners of such Facility Lender are claiming the portfolio interest exemption, such Facility Lender may provide a US Tax Compliance Certificate on behalf of each such direct and indirect partner;

 

-160-

Plaquemines – Amended & Restated Common Terms Agreement


  (iii)

any Facility Lender that is not a US Person shall, to the extent it is legally entitled to do so, deliver to the Borrower and its Facility Agent (in such number of copies as shall be requested by the recipient) on or prior to the date on which such Facility Lender becomes a Facility Lender under the relevant Facility Agreement (and from time to time thereafter upon the reasonable request of the Borrower or such Facility Agent) executed copies of any other form prescribed by applicable law as a basis for claiming exemption from or a reduction in US federal withholding Tax, duly completed, together with such supplementary documentation as may be prescribed by applicable law to permit the Borrower or such Facility Agent to determine the withholding or deduction required to be made; and

 

  (iv)

if a payment made to a Facility Lender under any Finance Document would be subject to US federal withholding Tax imposed by FATCA if such Facility Lender were to fail to comply with the applicable reporting requirements of FATCA (including those contained in Section 1471(b) or 1472(b) of the Code, as applicable), such Facility Lender shall deliver to the Borrower and its Facility Agent at the time or times prescribed by law and at such time or times reasonably requested by the Borrower or such Facility Agent such documentation prescribed by applicable law (including as prescribed by Section 1471(b)(3)(C)(i) of the Code) and such additional documentation reasonably requested by the Borrower or such Facility Agent as may be necessary for the Borrower and such Facility Agent to comply with their obligations under FATCA and to determine whether such Facility Lender has complied with such Facility Lender’s obligations under FATCA or to determine the amount to deduct and withhold from such payment. Solely for purposes of this sub-clause (iv), “FATCA” shall include any amendments made to FATCA after the Initial Closing Date.

 

  (c)

Any Facility Agent shall provide on or prior to the date it becomes a party to the Facility Agreement two executed copies of (i) if such Facility Agent is not a US Person, (x) with respect to payments made to such Facility Agent on behalf of a Facility Lender, IRS Form W-8IMY (or any successor form) certifying that it is a “U.S. branch” within the meaning of US Treasury Regulation Section 1.1441-1(b)(2)(iv)(A), with the effect that the Borrower may make payments to the Facility Agent, to the extent such payments are received by the Facility Agent as an intermediary, without deduction or withholding of any taxes imposed by the United States (including under FATCA), and (y) with respect to payments to such Facility Agent for its own account, IRS Form W-8ECI (or other applicable IRS Form W-8 establishing full exemption from all United States withholding taxes or any successor form), and (ii) if such Facility Agent is a US Person, IRS Form W-9 (or any successor form) confirming that the Facility Agent is exempt from US federal backup withholding.

 

-161-

Plaquemines – Amended & Restated Common Terms Agreement


  (d)

Each Facility Lender and Facility Agent agrees that if any form or certification it previously delivered expires or becomes obsolete or inaccurate in any respect, it shall update such form or certification or promptly notify the Borrower and the relevant Facility Agent in writing of its legal inability to do so.

 

  21.6

Refunds

To the extent that a Facility Lender or its Affiliate determines, in its sole discretion exercised in good faith, that it has obtained a refund or credit (in lieu of a refund) in respect of any Taxes as to which it has been indemnified pursuant to this Article 21 (Tax Gross-Up and Indemnities) (including by the payment of additional amounts pursuant to this Article 21 (Tax Gross-Up and Indemnities)), the relevant Facility Lender shall pay the Borrower an amount equal to such refund or credit, but only to the extent of indemnity payments made under this Article 21 (Tax Gross-Up and Indemnities) with respect to the Taxes giving rise to such refund or credit, and net of costs and expenses (including Taxes) and without interest (other than interest paid by the relevant Governmental Authority with respect to such refund or credit). The Borrower, upon the request of the Facility Lender or its Affiliate, shall repay to the Facility Lender or its Affiliate the amount paid over pursuant to the preceding sentence (plus any penalties, interest or other charges imposed by the relevant Governmental Authority) in the event that the Facility Lender or its Affiliate is required to repay such refund or credit to such Governmental Authority. Notwithstanding anything to the contrary in this paragraph, in no event shall the Facility Lender or its Affiliate be required to pay any amount to the Borrower pursuant to this paragraph the payment of which would place the Facility Lender or its Affiliate in a less favorable net after-Tax position than the Facility Lender or its Affiliate would have been in if the Tax subject to indemnification and giving rise to such refund or credit had not been deducted, withheld or otherwise imposed and the indemnification payments or additional amounts with respect to such Tax had never been paid. This paragraph shall not be construed to require any Facility Lender or its Affiliate to make available its Tax returns (or any other information relating to its Taxes that it deems confidential) to the Borrower or any other Person.

 

  21.7

Evidence of Payments

As soon as practicable after any payment of Taxes by any Obligor to a Governmental Authority pursuant to this Article 21 (Tax Gross-Up and Indemnities), such Obligor shall deliver to the relevant Facility Agent the original or a certified copy of a receipt issued by such Governmental Authority evidencing such payment, a copy of the return reporting such payment or other evidence of such payment reasonably satisfactory to the Facility Agent.

 

-162-

Plaquemines – Amended & Restated Common Terms Agreement


  21.8

Survival

Each Party’s obligations under this Article 21 (Tax Gross-Up and Indemnities) shall survive the resignation or replacement of any Facility Agent or any assignment of rights by, or the replacement of, a Facility Lender, the termination of the Facility Debt Commitments and the repayment, satisfaction or discharge of all obligations under any Finance Document.

 

  21.9

Defined Terms

For purposes of this Article 21 (Tax Gross-Up and Indemnities):

 

  (a)

the term “applicable law” includes FATCA;

 

  (b)

the term “US Person” means a “United States person” as such term is defined in Section 7701(a)(30) of the Code;

 

  (c)

the term “Finance Document” does not include any Indenture or Senior Notes;

 

  (d)

the term “Governmental Authority” includes any government of a foreign jurisdiction; and

 

  (e)

the term “Facility Agent” includes the Intercreditor Agent and the Collateral Agent, to the extent payments hereunder in respect of Senior Debt Obligations are made to it.

 

22.

INCREASED COSTS

 

  22.1

Increased Costs

 

  (a)

If any Change in Law shall:

 

  (i)

impose, modify or deem applicable any reserve, special deposit, compulsory loan, insurance charge or similar requirement against assets of, deposits with or for the account of, or credit extended or participated in by, any Facility Lender;

 

  (ii)

subject any Finance Party (or its Affiliates) to any Taxes (other than (x) Indemnified Taxes, (y) Taxes described in clauses (b) through (d) of the definition of Excluded Tax and (z) Connection Income Taxes) on its loans, loan principal, letters of credit, commitments or other obligations, or its deposits, reserves, other liabilities or capital attributable thereto; or

 

-163-

Plaquemines – Amended & Restated Common Terms Agreement


  (iii)

impose on any Facility Lender any other condition, cost or expense (other than Taxes) affecting this Agreement or Loans made by such Facility Lender or any letter of credit or participation in any such Loan or letter of credit;

and the result of any of the foregoing shall be to increase the cost to such Finance Party of making, converting to, continuing or maintaining any Loan (or of maintaining its obligation to make any such Loan, or to increase the cost to such Facility Lender of participating in, issuing or maintaining any letter of credit (or of maintaining its obligation to participate in or to issue any letter of credit)), or to reduce the amount of any sum received or receivable by such Finance Party hereunder (whether of principal, interest or any other amount) then, upon request of such Finance Party, the Borrower shall within the time period specified in clause (b) below pay to such Finance Party such additional amount or amounts as shall compensate such Finance Party for such additional costs incurred or reduction suffered (except to the extent the Borrower is excused from payment pursuant to Section 19.5 (Mitigation Obligations; Replacement of Lenders) or Section 19.8 (Resulting Increased Costs)).

 

  (b)

If any Facility Lender determines that any Change in Law regarding capital or liquidity requirements has or would have the effect of reducing the rate of return on such Facility Lender’s capital or (without duplication) on the capital of such Facility Lender’s holding company, if any, as a consequence of this Agreement, the Facility Debt Commitments of such Facility Lender or the Loans made by such Facility Lender or participations in letters of credit held by such Facility Lender to a level below that which such Facility Lender or such Facility Lender’s holding company could have achieved but for such Change in Law (taking into consideration such Facility Lender’s policies and the policies of such Facility Lender’s holding company with respect to capital adequacy and liquidity), then from time to time upon notice by such Facility Lender, the Borrower shall pay to such Facility Lender within 30 days following the receipt of such notice by the Facility Lender such additional amount or amounts as shall compensate such Facility Lender or (without duplication) such Facility Lender’s holding company for any such reduction suffered (except to the extent the Borrower is excused from payment pursuant to Section 19.5 (Mitigation Obligations; Replacement of Lenders) or Section 19.8 (Resulting Increased Costs)).

 

-164-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

The applicable Finance Party will deliver to the Borrower (with a copy to the Intercreditor Agent) a certificate setting forth in reasonable detail the amount or amounts necessary to compensate such Finance Party or its holding company, as the case may be, as specified in clauses (a) and (b) above. The Borrower shall pay such Finance Party the amount shown as due on any such certificate within 30 days after receipt thereof. Such certificate shall be conclusive absent manifest error.

 

  (d)

Failure or delay on the part of any Finance Party to demand compensation pursuant to this Section 22.1 (Increased Costs) shall not constitute a waiver of such Finance Party’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Finance Party pursuant to this Section 22.1 (Increased Costs) for any increased costs or reductions incurred or reductions suffered more than 180 days prior to the date that such Facility Lender notifies the Borrower of the Change in Law giving rise to such increased costs or reductions, and of such Facility Lender’s intention to claim compensation therefor (except that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 180 day period referred to above shall be extended to include the period of retroactive effect thereof).

 

  (e)

Notwithstanding any other provision in this Agreement, no Facility Lender shall demand compensation pursuant to this Article 22 (Increased Costs) in respect of the Change in Law arising from the matters described in the proviso to the definition of “Change in Law” if it shall not at the time be the general policy or practice of such Facility Lender, as determined by such Facility Lender, to demand such compensation in similar circumstances under comparable provisions of other credit agreements, if any. For the avoidance of doubt, this clause (e) shall not impose an obligation on a Facility Lender to provide information regarding compensation claimed and/or paid under any other specific loan agreement; provided that such Facility Lender shall, upon request from the Borrower, provide a written confirmation to the Borrower regarding whether it is the general policy or practice of such Facility Lender, as the case may be, to demand such compensation in similar circumstances under comparable provisions of other credit agreements.

 

  22.2

Relationship Between Increased Costs and Taxes

Any compensation of a Facility Lender pursuant to Article 21 (Tax Gross-Up and Indemnities) shall be made without duplication under this Article 22 (Increased Costs) and any compensation of a Facility Lender pursuant to this Article 22 (Increased Costs) shall be made without duplication under Article 21 (Tax Gross- Up and Indemnities).

 

-165-

Plaquemines – Amended & Restated Common Terms Agreement


23.

MISCELLANEOUS

 

  23.1

Termination

 

  (a)

Upon the occurrence of the Discharge Date in respect of the Senior Debt Obligations under this Agreement and each Facility Agreement, then, subject to reinstatement as provided in clause (c) below, this Agreement shall terminate and the Intercreditor Agent shall, at the expense of the Borrower, execute and deliver a termination statement.

 

  (b)

The obligations of the Facility Lenders to make further disbursements of Loans under their respective Facility Agreements shall terminate in accordance with the applicable Facility Agreement and, in any case, upon the termination of this Agreement, and the Security Interests of such Facility Lenders shall be discharged and released pursuant to Section 12.1 (Termination) of the Common Security and Account Agreement.

 

  (c)

This Agreement shall continue to be effective or be reinstated, as the case may be, if (and only to the extent that) any payment or performance of the obligations of the Borrower hereunder is rescinded, avoided, voidable, liable to be set aside, reduced or otherwise not properly payable to, or must otherwise be returned or restored by the Intercreditor Agent, any Facility Agent, the Collateral Agent or any Facility Lender as a result of (i) Bankruptcy, insolvency, reorganization with respect to the Borrower or the Intercreditor Agent, any Facility Agent, the Collateral Agent or any Facility Lender, (ii) upon the dissolution of, or appointment of any intervenor, conservator, trustee or similar official for the Borrower, the Intercreditor Agent, any Facility Agent, the Collateral Agent or any Facility Lender or for any substantial part of the Borrower’s or any other such Person’s assets, (iii) as a result of any settlement or compromise with any Person (including the Borrower) in respect of such payment or otherwise, or (iv) any similar event or otherwise and, in such case, the provisions of Section 10.1 (Nature of Obligations) of the Common Security and Account Agreement shall apply hereto mutatis mutandis.

 

  23.2

Right of Set-Off

Each Facility Lender, each Facility Agent and the Intercreditor Agent are hereby authorized at any time and from time to time, to the fullest extent permitted by law but subject to any other provision of this Agreement and the Finance Documents, to set off and apply any and all deposits (general or special, time or demand, provisional or final) at any time held and other indebtedness at any time owing by such Facility Lender, each Facility Agent or the Intercreditor Agent, as applicable, to or for the credit or the account of any Obligor, as applicable, against the Senior Debt Obligations due and payable to such Facility Lender, such Facility Agent or

 

-166-

Plaquemines – Amended & Restated Common Terms Agreement


the Intercreditor Agent, as applicable, at the time of such offset. If the obligations are in different currencies, the Facility Lender, the Facility Agent and the Intercreditor Agent, as applicable, may convert either obligation at a market rate of exchange in its usual course of business for the purposes of the set-off. The rights of each Facility Lender, each Facility Agent and the Intercreditor Agent under this Section 23.2 (Right of Set-Off) are in addition to other rights and remedies (including other rights of set-off) that such Facility Lender, such Facility Agent and the Intercreditor Agent, as applicable, may have. Each Facility Lender shall notify its respective Facility Agent and the Borrower forthwith upon the exercise or purported exercise of any right of set-off, giving full details in relation thereto, and such Facility Agent shall promptly inform the Intercreditor Agent in writing, who shall inform the other Facility Agents of the same. Any amounts set off by any Facility Lender in accordance with this Section 23.2 (Right of Set-Off) or under this Agreement shall be subject to the sharing arrangements set forth in Section 2.3(b) (Payments and Prepayments – Sharing of Non-Pro Rata Payments) of the Common Security and Account Agreement.

 

  23.3

Waiver of Immunity

To the extent that any Party hereto has or hereafter may acquire, or be entitled to claim for itself or its assets, any immunity from jurisdiction of any court or from any legal process (whether through service or notice, attachment in aid of execution, execution or otherwise) with respect to itself or its assets, it shall irrevocably agree not to claim and hereby irrevocably waives such immunity in respect of its obligations under the Finance Documents to which it is a party and all other documents to be executed and delivered in connection with the Finance Documents to which it is a party and the transactions contemplated thereby and, without limiting the generality of the foregoing, hereby agrees that the waivers set forth in this Section 23.3 (Waiver of Immunity) shall be effective to the fullest extent permitted under applicable law.

 

  23.4

Expenses

 

  (a)

The Borrower shall pay to the Intercreditor Agent or a Facility Agent, as the case may be, within 30 days of demand (such demand being made together with copies of invoices and reasonable supporting evidence of the nature and amount of such costs), without duplication in respect of indemnity and/or reimbursement required under any other Finance Document:

 

  (i)

to the extent such expenses have not been paid by the Borrower from the Initial Advance pursuant to Section 4.1(p) (Conditions to Initial Closing Date and Initial Advance – Fees; Expenses) or with proceeds on deposit in the Accounts on the Upsize Closing Date pursuant to Section 4.2(p) (Conditions to Upsize Closing Date – Fees; Expenses), the amount of all reasonable costs and expenses

 

-167-

Plaquemines – Amended & Restated Common Terms Agreement


  (including reasonable legal fees and expenses and excluding fees of Consultants, which shall be exclusively governed by Section 13.2 (Replacement and Fees)) incurred by any Facility Lender, Facility Agent or the Intercreditor Agent in connection with the negotiation, preparation, printing, execution and/or syndication of the Finance Documents to which it is a party, based upon fee parameters (if any, including the terms of the party’s applicable engagement or commitment letter, or Facility Agreement, as the case may be) agreed between the Borrower and the relevant parties;

 

  (ii)

the amount of all reasonable costs and expenses (including reasonable legal fees and expenses and excluding fees of Consultants, which shall be exclusively governed by Section 13.2 (Replacement and Fees)) incurred by any Facility Lender, Facility Agent or the Intercreditor Agent in connection with:

 

  (A)

the negotiation, preparation and execution of any Finance Document executed after the Initial Closing Date;

 

  (B)

any amendment, waiver or consent requested by or on behalf of the Borrower or specifically allowed by this Agreement, whether or not granted; and

 

  (C)

the exercise of its powers and the performance of its duties under this Agreement and any other Finance Documents; and

 

  (iii)

the amount of all costs and expenses (including legal fees and expenses and excluding fees of Consultants, which shall be exclusively governed by Section 13.2 (Replacement and Fees)) incurred by any Facility Lender, Facility Agent or the Intercreditor Agent in connection with the enforcement or preservation of any rights under any Finance Documents.

 

  (b)

The Facility Lenders, the Facility Agents and the Intercreditor Agent, as applicable, shall inform the Borrower on a regular basis of the ongoing costs and expenses referred to in clause (a) above.

 

  (c)

Notwithstanding anything to the contrary in this Section 23.4 (Expenses), the Facility Lenders, Facility Agents and the Intercreditor Agent shall only be entitled to the reimbursement of legal fees and expenses for the use of only one law firm engaged for all of the Facility Lenders, the Facility Agents and the Intercreditor Agent in each relevant jurisdiction unless one or more of the Facility Lenders, the Facility Agents or the Intercreditor Agent incurring such fees and expenses reasonably believes that there is a

 

-168-

Plaquemines – Amended & Restated Common Terms Agreement


  reasonable likelihood of a conflict of interest between any of them (the existence of which shall be notified to the Borrower) necessitating the use of more than one law firm in any such jurisdiction, in which case the fees and expenses of one additional firm in each relevant jurisdiction.

 

  (d)

Notwithstanding anything to the contrary in this Section 23.4 (Expenses), payment of expenses by the Borrower hereunder to be made to only a certain specified Facility Lender or Facility Lenders shall be received by the Intercreditor Agent or the relevant Facility Agent solely for the benefit of such Facility Lender or Facility Lenders, and the Borrower shall also be permitted to make the payment directly to such Facility Lender or Facility Lenders.

 

  (e)

This Section 23.4 (Expenses) shall not apply to Taxes, which shall be governed exclusively by Article 21 (Tax Gross-Up and Indemnities) and Article 22 (Increased Costs).

 

  23.5

Calculation of Floating Rate Obligations

In calculating amounts to be calculated under this Agreement, other than any interest payable on Senior Debt Obligations on which interest is payable at a floating rate of interest, if a floating rate is not known for the entire period, the floating rate to be used shall be reasonably estimated by the Borrower at the time of determination thereof.

 

  23.6

Severability

Any term or provision of this Agreement or the application thereof to any circumstance that is illegal, invalid, prohibited or unenforceable (to any extent) in any jurisdiction shall, as to such jurisdiction, be ineffective to the extent of such illegality, invalidity, prohibition or unenforceability without invalidating or rendering unenforceable the remaining terms or provisions hereof or the application of such term or provision to circumstances other than those to which it is held illegal, invalid, prohibited or unenforceable. Any such illegality, invalidity, prohibition or unenforceability in any jurisdiction shall not invalidate or render unenforceable such term or provision in any other jurisdiction and the Parties hereto shall enter into good faith negotiations to replace the invalid, illegal, prohibited, or unenforceable term or provision with a view to obtaining the same commercial effect as this Agreement would have had if such term or provision had been legal, valid, and enforceable. To the extent permitted by applicable laws, the Parties hereto waive any provision of law that renders any term or provision of this Agreement illegal, invalid, prohibited or unenforceable in any respect.

 

-169-

Plaquemines – Amended & Restated Common Terms Agreement


  23.7

Confidentiality

The provisions of Section 12.6 (Confidentiality) of the Common Security and Account Agreement are incorporated by reference and shall apply mutatis mutandis as if fully set forth herein.

 

  23.8

Notices

 

  (a)

Except in the case of notices and other communications expressly permitted to be given by telephone, all notices and other communications provided for herein shall be in writing in the English language (or, if not available in the English language, accompanied by an English language translation of such document) and shall be delivered by hand or overnight courier service, mailed by certified or registered mail, sent by email to the address, and/or email address of the Party to whom notice is being sent set forth below or on the Register maintained by the Facility Agent under each Facility Agreement in accordance with Section 19.7 (Register), which Register may, at each Facility Lender’s election, include email addresses for such Facility Lender:

 

  (i)

with respect to the Obligors, the corresponding address and other notice information set forth in Schedule Q – 1 (Addresses for Notices to Obligors);

 

  (ii)

with respect to each Facility Lender and Facility Agent, to the corresponding address and other notice information set forth in Schedule Q – 2 (Addresses for Notices to Facility Agents and Facility Lenders); and

 

  (iii)

with respect to the Intercreditor Agent, to:

Royal Bank of Canada, as Intercreditor Agent

155 Wellington Street West, 8th Floor

Toronto, Ontario M5V 3K7

Attention: Manager, Agency

Facsimile: [***]

Email: [***]

 

  (b)

Any notice, demand, consent or approval or communication given electronically by the Intercreditor Agent in connection with a Finance Document may be given to any Finance Party that has expressly agreed that it shall accept communication of information by this method by means of the Debt Domain Website, access to which is restricted to the parties to the Finance Documents, or by other electronic means in a manner and subject to rules established by the Intercreditor Agent and agreed with the Borrower; provided that the Intercreditor Agent may set access protocols as reasonably needed to communicate confidentially with the other Secured Parties at its sole discretion.

 

-170-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

Any Party may change its address, fax number or email address for notices and other communications hereunder by notice to the other Parties. All notices and other communications given to any Party in accordance with the provisions of this Agreement shall be deemed to have been received: (i) in the case of a letter, when delivered personally or five days after it has been put into the post; (ii) in the case of a fax, when a complete and legible copy is received by the addressee; (iii) in the case of email, upon receipt by the sender of a return receipt message (provided that, in the case of sub-clause (ii) above and this sub-clause (iii), if the date of dispatch is not a Business Day or the time of dispatch is after 5:00 pm in the location of dispatch, it shall be deemed to have been received no earlier than the opening of business on the next Business Day); and (iv) in the case of a notice contemplated by clause (b) above, on the later of (x) a notice being posted on the Debt Domain Website and (y) receipt by the Intercreditor Agent of a return receipt message in respect of an email the Intercreditor Agent has sent to the relevant Party’s email address (as notified to the Intercreditor Agent in writing at least five days before any email is sent by the Intercreditor Agent or notice posted on the Debt Domain Website) notifying such Party that the notice has become available on the Debt Domain Website.

 

  (d)

Communication by one Party to any other Party may, at the election of each such Party, be by electronic mail. For the purpose of the Finance Documents, an electronic communication will be treated as being in writing. Inclusion of an email address or addresses in the notice details for a Party shall indicate that such Party elects to receive and send communications by email subject to any particular requirements relating thereto of which it has notified each other Party. The absence of the notification of an email address shall indicate that such Party does not elect to receive or send communication by email, and any email communication to it shall be deemed not to have been delivered.

 

  (e)

In the event of any change in the identity of any of the authorized officers of the Obligors referred to in the documentary evidence provided for pursuant to Section 4.2(k) (Conditions to Upsize Closing Date – Bank Regulatory Requirements) and Section 4.2(l) (Conditions to Upsize Closing Date – Officer’s Certificates), the relevant Obligor shall promptly notify the Intercreditor Agent in writing of such change and, at the same time, furnish to the Intercreditor Agent certified signature specimen(s) in respect of the relevant Obligor’s new authorized officer(s). The Finance Parties may rely

 

-171-

Plaquemines – Amended & Restated Common Terms Agreement


  upon and refer to certified signature specimen(s) previously received by the Intercreditor Agent until such time as the Intercreditor Agent receives notice from the relevant Obligor of such change and the relevant certified signature specimen(s) to be furnished in connection therewith.

 

  (f)

Each of the Obligors and the other Parties to this Agreement:

 

  (i)

consents to the inclusion in the Debt Domain Website of its name, its logo and a link to its website, if any;

 

  (ii)

acknowledges that the Intercreditor Agent shall issue user identifiers, passwords and other information necessary for access to the Debt Domain Website (“Access Information”) to the Borrower and the other Parties to this Agreement;

 

  (iii)

undertakes to ensure that all Access Information issued to it by the Intercreditor Agent is kept secure and confidential in accordance with Section 12.6 (Confidentiality) of the Common Security and Account Agreement;

 

  (iv)

acknowledges that the Debt Domain Website is provided “as is” and “as available” and that the Intercreditor Agent does not warrant the accuracy or completeness of the communications or the adequacy of the Debt Domain Website and expressly disclaims liability for errors or omissions in the communications;

 

  (v)

acknowledges that no warranty of any kind, express implied or statutory, including any warranty of merchantability, fitness for a specific purpose, non-infringement of third party rights or freedom from viruses or other code defects, is made by the Intercreditor Agent in connection with the communications or the Debt Domain Website; and

 

  (vi)

agrees that neither the Intercreditor Agent nor any of its officers, directors, employees, agents, advisors or representatives is liable for damages of any kind, including direct or indirect, special, incidental or consequential, or any losses or expenses (whether in tort, contract or otherwise) incurred or suffered by it or any other Person as a result of its access or use of the Debt Domain Website or inability to access or use the Debt Domain Website (other than for its own gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final and non-appealable judgment).

 

-172-

Plaquemines – Amended & Restated Common Terms Agreement


  23.9

Successors and Assigns; Benefits of Agreement

This Agreement shall be binding upon and inure to the benefit of each of the Parties hereto (and the Facility Lenders claiming through the Parties hereto) and their subsequent respective permitted successors, permitted transferees and permitted assigns, and nothing in this Agreement, in any Senior Debt Instrument, in any Permitted Senior Debt Hedging Instrument, or in any other Finance Document, express or implied, shall give to any other Person any benefit or any legal or equitable right or remedy under this Agreement (other than the Parties hereto, their respective successors, transferees and assigns permitted hereby and, to the extent expressly contemplated thereby, the shareholders, members, partners, directors, officers, employees and agents of each of the Intercreditor Agent, Facility Agents, Facility Lenders and other indemnitees under Article 21 (Tax Gross-Up and Indemnities)).

 

  23.10

Remedies

 

  (a)

Other than as stated expressly herein, no remedy under this Agreement or any other Finance Document conferred on any Finance Party is intended to be exclusive of any other remedy, and each and every such remedy shall be cumulative and shall be in addition to every other remedy given under the Finance Documents, or now or hereafter existing at law or in equity or by statute or otherwise.

 

  (b)

The amounts payable by the Borrower at any time under this Agreement or any other Finance Document shall each be a separate and independent debt and each Finance Party, except as otherwise specifically provided in this Agreement or any other Finance Document, shall be entitled to protect and enforce its rights arising out of this Agreement or any other Finance Document, and its right, pursuant to this Agreement including any applicable Facility Agreements, to cancel or suspend its commitment to provide Senior Debt Obligations and to accelerate the maturity of amounts due under its Facility Agreement, and, except as aforesaid, it shall not be necessary for any other Finance Party to consent to, or be joined as an additional party in, any proceedings for such purposes.

 

  (c)

Except as otherwise specifically provided in this Agreement or any other Finance Document, no failure on the part of any Finance Party to exercise and no delay in exercising, and no course of dealing with respect to, any right, power or privilege under this Agreement or any other Finance Document, shall operate as a waiver thereof nor shall any single or partial exercise of any right, power or privilege under any such document preclude any other or further exercise thereof or the exercise of any other right, power or privilege. No Finance Party shall be responsible for the failure of any other Finance Party to perform its obligations hereunder or under any Facility Agreement.

 

-173-

Plaquemines – Amended & Restated Common Terms Agreement


  (d)

In case any Facility Lender or the Collateral Agent or the Intercreditor Agent on behalf of the Senior Creditors shall have proceeded to enforce any right, remedy or power under and in accordance with this Agreement or any Finance Document and the proceeding for the enforcement thereof shall have been discontinued or abandoned for any reason or shall have been determined adversely to such Facility Lender, then and in every such case the relevant Obligor and the Facility Lender shall, subject to any effect of or determination in such proceeding, severally and respectively be restored to their former positions and rights hereunder and under the Finance Documents, and thereafter all rights, remedies and powers of the Facility Lenders shall continue as though no such proceeding had been taken.

 

  (e)

The rights of each Facility Lender:

 

  (i)

may be exercised as often as necessary;

 

  (ii)

are cumulative and not exclusive of its rights under general law; and

 

  (iii)

may be waived only in writing and specifically.

 

  (f)

The undertakings by, and the obligations of, the Obligors set forth in this Agreement or in the Finance Documents are for the benefit of the Secured Parties alone, in accordance with the terms thereof.

 

  23.11

Execution in Counterparts; E-Signature

This Agreement may be executed in any number of counterparts and by the different Parties hereto on separate counterparts, each of which when so executed and delivered shall be an original, but all the counterparts shall together constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Agreement in electronic format (e.g., “pdf” or “tif”) shall be effective as delivery of a manually executed counterpart of this Agreement. The words “execution”, “execute”, “signed”, “signature”, and words of like import in or related to any document signed or to be signed in connection with this Agreement and the transactions contemplated hereby shall be deemed to include electronic signatures, the electronic matching of assignment terms and contract formations on electronic platforms approved by the parties hereto, or the keeping of records in electronic form, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper based recordkeeping system, as the case may be, to the extent and as provided for in any applicable law, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

 

-174-

Plaquemines – Amended & Restated Common Terms Agreement


  23.12

Governing Law

THIS AGREEMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK.

 

  23.13

Waiver of Jury Trial

EACH PARTY HERETO HEREBY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY AND ALL RIGHT TO TRIAL BY JURY IN ANY LEGAL PROCEEDING ARISING OUT OF OR RELATING TO THIS AGREEMENT, THE FINANCE DOCUMENTS OR THE TRANSACTIONS CONTEMPLATED THEREBY.

 

  23.14

Consent to Jurisdiction

 

  (a)

All Parties to this Agreement, as contemplated by Section 23.12 (Governing Law), shall consent to the exclusive jurisdiction of the courts of the State of New York or of the United States of America for the Southern District of New York (except as otherwise specifically provided herein).

 

  (b)

Each Party hereto:

 

  (i)

hereby irrevocably consents and agrees for the benefit of the Facility Lenders that the federal or state courts in the Borough of Manhattan, the City of New York shall have jurisdiction over any legal action, suit or proceeding against it with respect to its obligations, liabilities or any other matter under or arising out of, or in connection with, this Agreement and the Loans;

 

  (ii)

irrevocably waives any objection it may now or hereafter have to the laying of venue of any action or proceeding in any such court and any claim it may now or hereafter have that any action or proceeding has been brought in an inconvenient forum; and

 

  (iii)

irrevocably consents and agrees that the submission to the jurisdiction of the federal or state courts in the Borough of Manhattan, the City of New York shall not limit the rights of the Facility Lenders to bring any action or proceeding in any other court of competent jurisdiction nor shall the bringing of any action or the taking of any proceedings in any other jurisdiction (whether concurrently or not) limit such rights, in each case, to the extent permitted by applicable law.

 

-175-

Plaquemines – Amended & Restated Common Terms Agreement


  23.15

Amendments

 

  (a)

Except as otherwise expressly provided in this Agreement (including as provided in clause (b) below), this Agreement may be amended, modified or supplemented only by an agreement in writing signed by the Borrower, the Guarantor and the Intercreditor Agent on behalf of each Facility Agent (with copies to each Facility Agent). Except as otherwise expressly provided in the relevant agreement or document, no waiver or consent of any term or condition of this Agreement or any other Finance Document in favor of the Borrower or Guarantor or any other Party hereto or thereto by any Facility Lender, its Facility Agent or the Intercreditor Agent may be given or granted by such parties except in accordance with the Intercreditor Agreement. The Facility Lenders may not agree to amend, modify or supplement this Agreement except in accordance with the Intercreditor Agreement.

 

  (b)

The written agreement contemplated in clause (a) above shall not be required:

 

  (i)

to update the Construction Budget and Schedule in accordance with Section 10.9 (Construction Budget and Schedule) in circumstances where such update does not otherwise require approval of the Requisite Intercreditor Parties;

 

  (ii)

for a successor Intercreditor Agent to accede to this Agreement in accordance with Section 18.7 (Resignation and Succession);

 

  (iii)

for a replacement Facility Agent to accede to this Agreement in accordance with Section 19.3 (Replacement of Facility Agents);

 

  (iv)

for a new Facility Agent to accede to this Agreement in accordance with Section 19.4 (Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement);

 

  (v)

to make entries on Schedule Q – 1 (Addresses for Notices to Obligors) to update any notification addresses of any Party therein or to amend the description of the relevant Obligor’s authorized and issued equity capital and name and ownership interest of the Borrower’s member;

 

  (vi)

to update Schedule F (Material Permits) in accordance with the provisions of Section 10.4(b)(x) (Construction Reports);

 

-176-

Plaquemines – Amended & Restated Common Terms Agreement


  (vii)

to update the Qualified Gas Supplier list in the Gas Sourcing Plan as set forth in Section 12.27 (Gas Transportation Arrangements; Gas Purchase Arrangements); or

 

  (viii)

to update Schedule U (Real Property Documents) to reflect new or amended Real Property Documents referenced in clause (i) of the definition thereof.

 

  23.16

Conflicts

In case of any conflict or inconsistency between the main body of this Agreement and any Facility Agreements (including any promissory note delivered thereunder), this Agreement shall control.

 

  23.17

Effectiveness

This Agreement shall come into full force and effect on the date hereof.

 

  23.18

Limitations on Liability

No claim shall be made by any Party hereto or any of their respective Affiliates against any other Party hereto or any of their Affiliates, directors, employees, attorneys or agents for any special, indirect, consequential or punitive damages (whether or not the claim therefor is based on contract, tort or duty imposed by law), in connection with, arising out of or in any way related to the transactions contemplated by this Agreement or the other Finance Documents, Material Project Agreements or any act or omission or event occurring in connection therewith; and each Party hereby waives, releases and agrees not to sue upon any such claim for any such damages, whether or not accrued and whether or not known or suspected to exist in its favor; provided that this Section 23.18 (Limitations on Liability) shall not be construed to relieve any Obligor of any obligation it may otherwise have hereunder or under any Finance Document to indemnify any Secured Party or any applicable Related Party against any claim, cost, loss, expense (including reasonable legal fees and expenses), damage or liability, sustained or incurred by or asserted against such Secured Party or Related Party.

 

  23.19

Survival of Obligations

The provisions of Article 21 (Tax Gross-Up and Indemnities), Section 22.1 (Increased Costs), Section 23.3 (Waiver of Immunity), Section 23.4 (Expenses), Section 23.7 (Confidentiality), Section 23.8 (Notices), Section 23.9 (Successors and Assigns; Benefits of Agreement), Section 23.12 (Governing Law), Section 23.13 (Waiver of Jury Trial), Section 23.14 (Consent to Jurisdiction), Section 23.16 (Conflicts) and this Section 23.19 (Survival of Obligations) shall survive the termination of this Agreement.

 

-177-

Plaquemines – Amended & Restated Common Terms Agreement


  23.20

No Fiduciary Duty

Each Finance Party and its respective Affiliates (collectively, solely for purposes of this Section 23.20 (No Fiduciary Duty) and in their capacity as a Finance Party, the “Lenders”) may have economic interests that conflict with those of the Borrower, the Guarantor, the Sponsor or any of their Affiliates. The Obligors on behalf of themselves, the Sponsor, and any Affiliate thereof respectively agree that nothing in the Finance Documents or otherwise will be deemed to create an advisory, fiduciary or agency relationship or fiduciary or other implied duty between any Lender, on the one hand, and any of the Borrower, the Guarantor, or the Sponsor or their Affiliates, on the other hand. The Obligors acknowledge and agree that (i) the transactions contemplated by the Finance Documents (including the exercise of rights and remedies hereunder and thereunder) are arm’s-length commercial transactions between the Facility Lenders, on the one hand, and the relevant Obligors, on the other hand, and (ii) in connection therewith and with the process leading thereto, (x) no Lender has assumed an advisory or fiduciary responsibility in favor of the Borrower, the Guarantor, the Sponsor or any of their Affiliates with respect to the transactions contemplated hereby (or the exercise of rights or remedies with respect thereto) or the process leading thereto (irrespective of whether any Lender has advised, is currently advising or shall advise the Borrower, the Guarantor, the Sponsor or any of their Affiliates on other matters) or any other obligation of the relevant Obligor except the obligations expressly set forth in the Finance Documents and (y) each Facility Lender is acting solely as principal and not as the agent or fiduciary of the Borrower, the Guarantor, the Sponsor or any of their Affiliates or any other Person. Each of the Obligors acknowledges and agrees that it has consulted its own legal and financial advisors to the extent it deemed appropriate and that it is responsible for making its own independent judgment with respect to such transactions and the process leading thereto. Each of the Obligors agrees that it shall not claim that any Lender has rendered advisory services of any nature or respect, or owes a fiduciary or similar duty to the respective Obligor, in connection with such transactions or the process leading thereto.

 

  23.21

USA Patriot Act Notice

Each Facility Lender that is subject to the requirements of the USA Patriot Act, each Facility Agent (for itself and not on behalf of any Facility Lender) and the Intercreditor Agent (for itself and not on behalf of any Facility Lender) hereby notifies each Obligor that pursuant to the requirements of the USA Patriot Act, it is required to obtain, verify and record information that identifies each Obligor, which information includes the name, taxpayer identification number and business address of each Obligor and other information that shall allow such Facility Lender, Facility Agent or the Intercreditor Agent, as applicable, to identify each Obligor in accordance with the USA Patriot Act.

 

-178-

Plaquemines – Amended & Restated Common Terms Agreement


  23.22

Limited Recourse

Subject to clause (b) below, each Secured Party that is a party hereto acknowledges and agrees that the obligations of the Obligors and the Pledgor under this Agreement and the other Finance Documents, including with respect to the payment of the principal of or premium or penalty, if any, or interest on any Senior Debt Obligations, or any part thereof, or for any claim based thereon or otherwise in respect thereof or related thereto, are obligations solely of the Obligors and the Pledgor (as applicable) and shall be satisfied solely from the security and assets of the Obligors and the Pledgor and shall not constitute a debt or obligation of Affiliates of Borrower (other than the other Obligor or the Pledgor), nor of any past, present or future shareholders, partners, members, directors, officers, employees, agents, attorneys or representatives of the Obligors and their Affiliates (collectively (but excluding the Obligors and the Pledgor), the “Non-Recourse Parties”).

 

  (a)

Each Secured Party that is a party hereto acknowledges and agrees that, subject to clause (b) below, the Non-Recourse Parties shall not be liable for any amount payable under this Agreement or any other Finance Document, and no Secured Party shall seek a money judgment or deficiency or personal judgment against any Non-Recourse Party for payment or performance of any obligation of the Obligors under this Agreement or the other Finance Documents.

 

  (b)

The acknowledgments, agreements and waivers set out in this Section 23.22 (Limited Recourse) shall be enforceable by any Non-Recourse Party and are a material inducement for the execution of this Agreement and the other Finance Documents by the Obligors; provided, however, that:

 

  (i)

the foregoing provisions of this Section 23.22 (Limited Recourse) shall not constitute a waiver, release or discharge of either Obligor or the Pledgor for any of the Indebtedness or Senior Debt Obligations of either Obligor or the Pledgor under, or any terms, covenants, conditions or provisions of, this Agreement or any other Finance Document to which any of the foregoing are party, and the same shall continue until fully and paid, discharged, observed or performed;

 

  (ii)

the foregoing provisions of this Section 23.22 (Limited Recourse) shall not limit or restrict the right of any Secured Party to name Borrower, the Guarantor, the Pledgor or any other Person as defendant in any action or suit for a judicial foreclosure or for the exercise of any other remedy under or with respect to this Agreement, any of the Security Documents or any other Finance Document to which such Person is a party, or for injunction or specific performance, so long as no judgment in the nature of a deficiency judgment shall be enforced against any Non-Recourse Party out of any property other than the property of Borrower, the Guarantor, the Pledgor, or the Collateral;

 

-179-

Plaquemines – Amended & Restated Common Terms Agreement


  (iii)

the foregoing provisions of this Section 23.22 (Limited Recourse) shall not in any way limit, reduce, restrict or otherwise affect any right, power, privilege or remedy of the Secured Parties (or any permitted assignee or beneficiary thereof or successor thereto) with respect to, and each and every Person (including each and every Non-Recourse Party) shall remain fully liable to the extent that such Person would otherwise be liable for its own actions with respect to, any fraud, bad faith, gross negligence or willful misrepresentation, or willful misappropriation of revenues or any other earnings, rents, issues, profits or proceeds from or of Borrower, the Guarantor, the Pledgor, the Project Facilities or the Collateral that should or would have been paid as provided in the Finance Documents or paid or delivered to the Collateral Agent (or any assignee or beneficiary thereof or successor thereto) for any payment required under this Agreement or any other Finance Document; and

 

  (iv)

nothing contained herein shall limit the liability of: (x) any Person who is a party to any Finance Document, Material Project Agreement or Security Document or (y) any Person rendering a legal opinion pursuant to Article 4 (Conditions Precedent) of this Agreement or otherwise, in each case under this clause (iv) relating solely to such liability of such Person as may arise under such referenced agreement, instrument or opinion.

The limitations on recourse set forth in this Section 23.22 (Limited Recourse) shall survive the Discharge Date.

 

  23.23

Entire Agreement

This Agreement (including Schedules), the Security Documents and the other Finance Documents (together with any other agreements or documents referred to or incorporated by reference therein) constitute the entire agreement and understanding, and supersede all prior agreements and understandings (both written and oral), between or among any of the Parties hereto relating to the transactions contemplated hereby or thereby other than any such agreements and undertakings contained in any commitment letter or fee letter related to the Loans stated expressly to survive the execution and delivery of this Agreement, among the Borrower, on the one hand, and the Facility Lenders, on the other hand.

 

-180-

Plaquemines – Amended & Restated Common Terms Agreement


  23.24

Tax Treatment

Each party hereto agrees (a) that the Loans are intended to be treated as debt for U.S. federal income tax purposes, and (b) to report the Loans on their U.S. federal income tax returns in a manner consistent with this Section 23.24 (Tax Treatment) unless otherwise required pursuant to a “determination” within the meaning of Section 1313(a) of the Code.

 

  23.25

Amendment and Restatement Except as expressly set forth herein, it is the intention of each of the parties hereto that:

 

  (a)

this Agreement does not constitute a novation of the obligations and liabilities of the parties under the Original Common Terms Agreement or the other Original Finance Documents as in effect prior to the Upsize Closing Date and that remain outstanding as of the Upsize Closing Date (including, without limitation, all Liens and security interests in the Collateral created under the Security Documents);

 

  (b)

this Agreement (including all Exhibits and Schedules attached hereto) amends, restates, replaces and supersedes in its entirety the Original Common Terms Agreement (including all Exhibits and Schedules attached thereto) on the Upsize Closing Date and the Original Common Terms Agreement (including all Exhibits and Schedules attached thereto) thereafter shall be of no further force and effect, apart from the provisions that pursuant to the terms of the Original Common Terms Agreement survive the termination thereof;

 

  (c)

this Agreement constitutes an amendment of the Original Common Terms Agreement made under and in accordance with the terms of Section 23.15 of the Original Common Terms Agreement and, in connection therewith, the amendments set forth herein shall be binding upon all of the parties to the Original Common Terms Agreement with the written consent of the Intercreditor Agent immediately prior to giving effect to this Agreement on the Upsize Closing Date;

 

  (d)

from and after the Upsize Closing Date, all references to the “Common Terms Agreement” contained in the Finance Documents (including all exhibits, schedules, annexes and other attachments attached hereto) shall be deemed to refer to this Agreement and all references to any section (or subsection) of this Agreement in any other Finance Document shall be amended to become, mutatis mutandis, references to the corresponding provisions of this Agreement; and

 

-181-

Plaquemines – Amended & Restated Common Terms Agreement


  (e)

all Senior Debt Obligations (as modified by this Agreement on the Upsize Closing Date) continue to be valid, enforceable and in full force and effect and not be impaired, in any respect, by the effectiveness of this Agreement.

 

-182-

Plaquemines – Amended & Restated Common Terms Agreement


IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be duly executed as of the say and year first above written.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC,
as the Company
By:   /s/ Jonathan W. Thayer
Name:   Jonathan W. Thayer
Title:   Chief Financial Officer

 

VENTURE GLOBAL GATOR EXPRESS, LLC,
as the Guarantor
By:   /s/ Jonathan W. Thayer
Name:   Jonathan W. Thayer
Title:   Chief Financial Officer

Signature Page to Amended and Restated Common Terms Agreement


NATIXIS, NEW YORK BRANCH,
as Credit Facility Agent
By:   /s/ Lisa Wong
Name:   Lisa Wong
Title:   Director

 

By:   /s/ Frederic Bouley
Name:   Frederic Bouley
Title:   Director

Signature Page to Amended and Restated Common Terms Agreement


ROYAL BANK OF CANADA,
as Intercreditor Agent
By:   /s/ Helen Sadowski
Name:   Helen Sadowski
Title:   Manager, Agency

Signature Page to Amended and Restated Common Terms Agreement


SCHEDULE A

COMMON DEFINITIONS AND RULES OF INTERPRETATION

 

1.1

Amendments

No amendment to any definition or rule of interpretation in this schedule shall be effective for purposes of any individual Finance Document unless such amendment has complied with the requirements for amendments to that Finance Document.

 

1.2

Interpretation

In this Agreement and in the Appendices, Exhibits and Schedules hereto, except to the extent that the context otherwise requires:

 

  (a)

the Table of Contents and headings are for convenience only and shall not affect the interpretation of this Agreement;

 

  (b)

unless otherwise specified, references to Articles, Sections, clauses, Appendices, Exhibits and Schedules are references to Articles, Sections and clauses of, and Appendices, Exhibits and Schedules to, this Agreement;

 

  (c)

references to any document or agreement shall be deemed to include references to such document or agreement as amended (however fundamentally), supplemented or replaced from time to time in accordance with its terms and (where applicable) subject to compliance with the requirements set forth herein and therein; provided that with respect to any references to the Equator Principles, such references shall be deemed to refer to such documents in effect as of the Upsize Closing Date, without regard to any amendments, supplements or replacements thereof after such date;

 

  (d)

references to any party to this Agreement or any other document or agreement shall include its successors and permitted transferees and assigns;

 

  (e)

an “authorization” includes an authorization, consent, approval, resolution, license, exemption, filing, registration and notarization;

 

  (f)

a “month” is a reference to a period starting on one day in a calendar month and ending on the numerically corresponding day in the next calendar month, except that, if there is no numerically corresponding day in the month in which that period ends, that period shall end on the last day in that month;

 

  (g)

words importing the plural include the singular and vice versa;

 

-183-

Plaquemines – Amended & Restated Common Terms Agreement


  (h)

whenever the context may require, any pronoun shall include the corresponding masculine, feminine and neuter forms;

 

  (i)

the words “include”, “includes” and “including” shall be deemed to be followed by the phrase “without limitation”;

 

  (j)

the word “will” shall be construed to have the same meaning and effect as the word “shall”;

 

  (k)

law” shall be construed as any law (including common or customary law), statute, constitution, decree, judgment, treaty, regulation, directive, by-law, order, ordinance or any other legislative measure of any government, supranational, local government, statutory or regulatory body or court, in each case having the force of law;

 

  (l)

unless as otherwise provided, any reference to assignment of a person’s rights and/or obligations shall be construed to refer to assignment, transfer or novation of those rights and/or obligations;

 

  (m)

any reference to the actions or omissions of agents, representatives or authorized persons shall refer only to actions or omissions taken in connection with the agency, representation or authorization (so that, for example, an action or omission of a contractor for any Obligor shall be the action of an agent, representative or authorized person of the Obligors only if taken in connection with the performance of its work under its contract with any Obligor involving work related to the Development, and shall not be the action or omission of an agent, representative or authorized person of the Obligors if taken under another contract with persons other than the Obligors involving work unrelated to the Development);

 

  (n)

the omission of the word “any” or the phrase “if any” with respect to anything shall not imply that the thing exists or is required, notwithstanding the inclusion of such word or phrase (for clarity) in other provisions;

 

  (o)

any reference to an action being taken “pursuant to” an agreement or document, or any specified provision thereof, shall be construed to mean “pursuant to and in compliance with” the requirements of such agreement, document or provision;

 

  (p)

in some instances, a word or reference that, pursuant to these rules of interpretation, is not necessary (for example, inclusion of both the singular and plural), may be included for emphasis or clarity, and any such usage shall not give rise to any negative implication in relation to any other usage, which other usage shall nonetheless be interpreted strictly in accordance with the rules of interpretation set forth herein;

 

-184-

Plaquemines – Amended & Restated Common Terms Agreement


  (q)

unless the contrary indication appears, a reference to a time of day is a reference to the time of day in New York, New York, United States; and

 

  (r)

the words “hereof”, “herein”, “hereto” and “hereunder” and words of similar import when used in this Agreement shall refer to this Agreement as a whole and not to any particular provision of this Agreement.

 

1.3

Definitions

“Abandonment” means any of the following shall have occurred:

 

  (a)

the abandonment, suspension or cessation of all or substantially all of the activities related to the Development or the abandonment, suspension or cessation of operations of the Project Facilities, in each case, for a period in excess of 60 consecutive days (other than as a result of force majeure so long as the Borrower is diligently attempting to restart the Development or the Project Facilities); provided that if this is not accompanied by a formal, public announcement by the Borrower of its intentions as set forth in clause (b) below, such abandonment, suspension or cessation shall not have occurred unless, within 45 days following notice to the Borrower from the Collateral Agent (who may be instructed by any Senior Creditor Group to deliver such notice) requesting the Borrower to deliver a certificate to the effect that it will resume construction or operation as soon as is commercially reasonable, the Borrower has not delivered such certificate or resumed such activities or, if such certificate is delivered, the Borrower has nevertheless not resumed such activities within 90 days following receipt of the notice from the Collateral Agent;

 

  (b)

a formal, public announcement by the Borrower of a decision to abandon, cease or indefinitely defer or suspend the Development for any reason; or

 

  (c)

the Borrower shall make any filing with FERC giving notice of the intent or requesting authority to abandon the Development for any reason.

Acceptable Bank” means a bank or financing entity whose (or whose parent company or guarantor in respect of the relevant letter of credit) long-term unsecured and unguaranteed debt is rated at least A3 by Moody’s and at least A- by S&P.

 

-185-

Plaquemines – Amended & Restated Common Terms Agreement


Acceptable Debt Service Reserve LC” means an irrevocable, standby letter of credit issued:

 

  (a)

by an Acceptable Bank under any Working Capital Debt, including pursuant to the Working Capital Facility that includes the following material terms:

 

  (i)

an expiration date no earlier than 364 days following its issuance date; and

 

  (ii)

allows the Collateral Agent to make a drawdown of up to the stated amount in each of the circumstances described in Section 4.9(d) (Acceptable Debt Service Reserve LC) of the Common Security and Account Agreement; or

 

  (b)

by an Acceptable Bank for the benefit of the Collateral Agent that includes the following material terms:

 

  (i)

an expiration date no earlier than 364 days following its issuance date;

 

  (ii)

allows the Collateral Agent to make a drawdown of up to the stated amount in each of the circumstances described in Section 4.9(d) (Acceptable Debt Service Reserve LC) of the Common Security and Account Agreement;

 

  (iii)

is not secured by the Collateral; and

 

  (iv)

the reimbursement and other payment obligations with respect to such letter of credit are not for the account of any Obligor.

Acceptable Lender” means any Sponsor or its Affiliate or a bank, financial institution, multilateral agency, development financial institution, trust, Approved Fund, insurance company, investment or mutual fund or other entity that is an “accredited investor” (as defined in Regulation D under the Securities Act) or any Senior Creditor (other than the Senior Noteholders that are not otherwise Acceptable Lenders) or any Affiliate of a Facility Lender or any other entity or Person, that in each case is regularly engaged in or established for the purpose of making, purchasing or investing in loans, securities or other financial assets (including credit derivatives) in the ordinary course of business; provided that, in the case of trusts and funds that are not Approved Funds, such entity shall be experienced in the financing of energy and natural resource projects; provided, further, that no Disqualified Institution shall be an “Acceptable Lender” hereunder.

Access Information” has the meaning given in Section 23.8(f)(ii) (Notices) of the Common Terms Agreement.

Access License Agreements” mean:

 

  (a)

Access License Agreement, dated as of January 19, 2022, by and between Plaquemines Land Ventures, LLC, as grantor, and the Borrower, as grantee (Tracts DR-4A, F-1, G and B-1); and

 

-186-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

Access License Agreement, dated as of April 1, 2022, between Plaquemines Land Ventures, LLC, as grantor, and Borrower as grantee.

Accession Agreement” means any accession agreement contemplated under the Finance Documents, the form of which is included in either Schedule D (Forms of Accession Agreements) to the Common Security and Account Agreement or Schedule P – 1 (Replacement Facility Agent Accession Agreement) and Schedule P

– 2 (New Facility Agent Accession Agreement (Additional Senior Debt)) to the Common Terms Agreement.

Account Bank” means, initially, City National Bank acting in its capacity as such (with any replacement to the initial Account Bank having a then-current credit rating at appointment by S&P at least equivalent to A+ or by Moody’s at least equivalent to A1 and being subject to receipt of consent in accordance with Section 9.9(b) (Resignation, Removal and Replacement of Account Bank) of the Common Security and Account Agreement).

Account Bank Fee Letter” means the amended and restated fee letter dated as of the Upsize Closing Date entered into between the Borrower, the Guarantor and the Account Bank in respect of the fees payable to the Account Bank in respect of its services to be performed as more fully described in the Common Security and Account Agreement and the other Security Documents.

Accounts” has the meaning given in Section 4.3(a) (Accounts) of the Common Security and Account Agreement.

ACQ” has the meaning given in the applicable LNG SPA.

Additional Debt Service Reserve Account(s)” means each Account established pursuant to Section 4.3(a) (Accounts) of the Common Security and Accounts Agreement.

Additional Proceeds Prepayment Account” means the account described in Section 4.3(a)(xii) (Accounts) of the Common Security and Account Agreement.

Additional Senior Debt” has the meaning given in Section 2.2(a)(i) (Incremental Senior Debt) of the Common Security and Account Agreement.

Administrative Services Agreements” mean the agreements between the Obligors and the Manager for their respective Project Facilities.

Advance” means a borrowing of a loan, issuance of or drawing upon a letter of credit or the issuance of debt securities pursuant to any Senior Debt Instrument.

Affected Financial Institution” means (a) any EEA Financial Institution or (b) any UK Financial Institution.

 

-187-

Plaquemines – Amended & Restated Common Terms Agreement


“Affiliate” of any specified Person means any other Person directly or indirectly Controlling or Controlled by or under direct or indirect common Control with such specified Person and “Affiliated” shall be construed accordingly.

Affiliated Service Counterparties” means the Operator, the Pipeline Operator, Plaquemines Tug Services, LLC, and the Manager.

Agreement” in each case where used means only the agreement in which the term is used. For the avoidance of doubt, (a) any reference to an individual Senior Debt Instrument which is a Facility Agreement shall be deemed to include reference to the Common Terms Agreement; and (b) references to an Indenture, or to any individual Senior Debt Instrument that is an Indenture, shall be deemed not to include reference to the Common Terms Agreement.

“Amortization Schedule”, with respect to a Facility Agreement, has the meaning given in such Facility Agreement.

Anti-Terrorism and Money Laundering Laws” means any of the following (a) Section 1 of Executive Order 13224 of September 24, 2001, Blocking Property and Prohibiting Transactions With Persons Who Commit, Threaten to Commit, or Support Terrorism, (b) the Terrorism Sanctions Regulations (Title 31 Part 595 of the US Code of Federal Regulations), (c) the Terrorism List Governments Sanctions Regulations (Title 31 Part 596 of the US Code of Federal Regulations),

(d) the Foreign Terrorist Organizations Sanctions Regulations (Title 31 Part 597 of the US Code of Federal Regulations), (e) the USA Patriot Act of 2001 (Pub. L. No. 107-56), (f) the US Money Laundering Control Act of 1986 (i.e., Laundering of Monetary Instruments, 18 U.S.C. section 1956, and Engaging in Monetary Transactions in Property Derived from Specified Unlawful Activity, 18 U.S.C. section 1957), (g) the Bank Secrecy Act, 31 U.S.C. sections 5301 et seq., (h) the Financial Recordkeeping and Reporting of Currency and Foreign Transactions Regulations (Title 31 Chapter X of the US Code of Federal Regulations), (i) any other similar federal Government Rule having the force of law and relating to money laundering, terrorist acts or acts of war and (j) any regulations promulgated under any of the foregoing.

Applicable Anti-Corruption Laws” means the U.S. Foreign Corrupt Practices Act of 1977, as amended, and all similar laws, rules, and regulations of any jurisdiction applicable to the Borrower, the Borrower’s Subsidiaries or any Guarantor at the relevant time concerning or relating to bribery or corruption.

Approved Fund” means any Fund administered or managed by (a) a Facility Lender, (b) an Affiliate of a Facility Lender or (c) an entity or an Affiliate of an entity that administers or manages a Facility Lender.

 

-188-

Plaquemines – Amended & Restated Common Terms Agreement


Approved Owner” means any Person that is approved by the Required Intercreditor Parties.

ASC 842” means the Accounting Standards Update No. 2021-05, Leases (Topic 842) issued by the Financial Accounting Standards Board in July 2021.

Authorized Investments” means any US Dollar denominated investments that are:

 

  (a)

direct obligations of, or obligations the principal and interest on that are unconditionally guaranteed by, the United States of America (or any instrumentality thereof to the extent such obligations are backed by the full faith and credit of the United States of America), in each case maturing within one year from the date of acquisition thereof;

 

  (b)

investments in marketable general obligations issued by any state of the United States of America or any political subdivision of any such state or any public instrumentality thereof in each case maturing within one year from the date of acquisition thereof and having, at such date of acquisition, a credit rating of “A” or higher from S&P or from Moody’s (or if at such time neither is issuing ratings, then a comparable rating of such other nationally recognized rating agency as shall be approved by the Collateral Agent in its reasonable judgment);

 

  (c)

commercial paper or tax exempt obligations having one of the two highest ratings obtainable from Moody’s or S&P (or if at such time neither is issuing ratings, then a comparable rating of such other nationally recognized rating agency as shall be approved by the Collateral Agent in its reasonable judgment) and, in each case, maturing within one year of acquisition thereof;

 

  (d)

investments in certificates of deposit, banker’s acceptances and time deposits maturing or putable within one year from the date of acquisition thereof issued or guaranteed or placed with, and money market deposit accounts issued or offered by, any domestic office of (i) a commercial bank organized under the laws of the United States of America or any state thereof or (ii) a licensed branch of a foreign bank organized under the laws of any member country of the Organization for Economic Co-Operation and Development, in either case, that has a combined capital and undivided surplus and undivided profits of at least $500 million;

 

  (e)

fully collateralized repurchase agreements with a term of not more than 30 days for securities described in clause (a) of this definition and entered into with a financial institution satisfying the criteria described in clause (d) of this definition; or

 

-189-

Plaquemines – Amended & Restated Common Terms Agreement


  (f)

money market funds that (i) comply with the criteria set forth in Securities and Exchange Commission Rule 2a-7 (or any successor rule) under the Investment Company Act of 1940; (ii) are rated either AAA by S&P and Aaa by Moody’s or at least 95% of the assets of which constitute Authorized Investments described in clauses (a) through (e) of this definition and/or US Dollars; and (iii) have portfolio assets of at least $500 million.

Authorized Officer” means: (a) with respect to any Person that is a corporation, the chairman, president, senior vice president, vice president, chief financial officer, chief operating officer, treasurer, assistant treasurer, attorney-in-fact, secretary or assistant secretary of such Person, (b) with respect to any Person that is a partnership, the chairman, president, senior vice president, vice president, chief financial officer, chief operating officer, treasurer, assistant treasurer, attorney-in- fact, secretary or assistant secretary of such Person or a general partner of such Person and (c) with respect to any Person that is a limited liability company, the chairman, president, senior vice president, chief financial officer, chief operating officer, vice president, treasurer, assistant treasurer, attorney-in-fact, secretary or assistant secretary, the manager, the managing member or a duly appointed officer of such Person.

Availability Period” means, (a) with respect to the Term Loans, the Term Loan Availability Period, (b) with respect to the Working Capital Loans, the Working Capital Loan Availability Period, (c) with respect to Letters of Credit, the Working Capital Loan Availability Period, and (d) with respect to any other Loans, the period commencing on the date of first disbursement of such Loans and ending on the date of the termination or cancellation of all remaining Facility Debt Commitments pursuant to the terms of the corresponding Facility Agreement.

Bail-In Action” means the exercise of any Write-Down and Conversion Powers by the applicable Resolution Authority in respect of any liability of an Affected Financial Institution.

Bail-In Legislation” means, (a) with respect to any EEA Member Country implementing Article 55 of Directive 2014/59/EU of the European Parliament and of the Council of the European Union, the implementing law, regulation, rule or requirement for such EEA Member Country from time to time that is described in the EU Bail-In Legislation Schedule and (b) with respect to the United Kingdom, Part I of the United Kingdom Banking Act 2009 (as amended from time to time) and any other law, regulation or rule applicable in the United Kingdom relating to the resolution of unsound or failing banks, investment firms or other financial institutions or their affiliates (other than through liquidation, administration or other insolvency proceedings).

 

-190-

Plaquemines – Amended & Restated Common Terms Agreement


Bankruptcy” means with respect to any Person, the occurrence of any of the following events, conditions or circumstances:

 

  (a)

such Person shall file a voluntary petition in bankruptcy, or shall file any petition or answer or consent seeking any reorganization, arrangement, adjustment, composition, insolvency, liquidation, receivership, dissolution or similar relief for itself under the Bankruptcy Code or any present or future applicable federal, state or other statute or law relating to bankruptcy, insolvency, reorganization or other relief for debtors generally, or shall apply for or consent to the appointment of any trustee, receiver, conservator or liquidator of such Person or of all or any substantial part of its properties;

 

  (b)

a case or other proceeding shall be commenced against such Person in a court of competent jurisdiction without the consent or acquiescence of such Person seeking any reorganization, arrangement, adjustment, composition, insolvency, liquidation, receivership, dissolution or similar relief with respect to such Person or its debts under the Bankruptcy Code or any present or future applicable federal, state or other statute or law relating to bankruptcy, insolvency, reorganization or other relief for debtors generally, or seeking the appointment of a trustee, receiver, liquidator, custodian or other similar official of it or any substantial part of its property, and such involuntary case or other proceeding shall remain undismissed or unstayed for a period of 60 consecutive days;

 

  (c)

a court of competent jurisdiction shall enter an order, judgment or decree approving a petition with respect to such Person seeking a reorganization, arrangement, composition, readjustment, liquidation, dissolution or similar relief under the Bankruptcy Code, or any other present or future applicable federal, state or other statute or law relating to bankruptcy, insolvency, reorganization or other relief for debtors, and such Person shall consent to the entry of such order, judgment or decree or such order, judgment or decree shall remain undischarged, unvacated or unstayed for 90 days (whether or not consecutive) from the date of entry thereof, or any trustee, receiver, conservator or liquidator of such Person or of all or any substantial part of its property shall be appointed without the consent of such Person and such appointment shall remain undischarged, unvacated and unstayed for an aggregate of 90 days (whether or not consecutive);

 

  (d)

such Person shall admit in writing its inability to pay its debts as they mature or shall generally not be paying its debts as they become due;

 

  (e)

such Person shall make a general assignment for the benefit of creditors or take any other similar action for the protection or benefit of creditors; or

 

  (f)

the board of directors, board of managers or similar body, or the member(s) of such Person shall take any corporate or partnership action for the purpose of effecting any of the foregoing.

 

-191-

Plaquemines – Amended & Restated Common Terms Agreement


Bankruptcy Code” means the United States Bankruptcy Reform Act of 1978 and codified as 11 U.S.C. Section 11 et seq.

Bankruptcy Default” has the meaning given in Section 6.2(c) (Initiation of Security Enforcement Action Bankruptcy Default) of the Common Security and Account Agreement.

Bankruptcy Proceeding” means:

 

  (a)

any case, action or proceeding before any court or other governmental authority in relation to a Bankruptcy; or

 

  (b)

a general assignment under clause (e) of the definition of Bankruptcy, in each case of (a) and (b) above, undertaken under applicable US federal, state or foreign law, including the Bankruptcy Code.

Base Case Forecast” means the base case forecast attached as Schedule R (Base Case Forecast) to the Common Terms Agreement as of the Upsize Closing Date, as may be updated from time to time in accordance with the Common Terms Agreement.

Base Case Sizing Criteria” means (a) beginning with the Project Phase 2 Completion Date and for each calendar year thereafter (through the underlying amortization period of the Upsized Senior Debt), including any stub year, a minimum Fixed Projected DSCR of the Upsize Closing Date DSCR and (b) a Senior Debt/Equity Ratio of no greater than 75:25, based, in each case, on Cash Flow Available for Debt Service from the fixed component under the Initial LNG SPAs and, solely to the extent when sizing the amount of any mandatory prepayment after the Upsize Closing Date, any Qualifying LNG SPAs that are then in full force and effect and on a 20 year amortization profile, and assuming no lifting of LNG and no merchant sales of LNG.

Base Committed Quantity” means (a) prior to the Upsize Closing Date, 13.0 MTPA of LNG from the Phase 1 Project Facilities, being the aggregate ACQ under the Phase 1 Initial LNG SPAs (except the Phase 1 Excess Capacity LNG SPA) and (b) on and following the Upsize Closing Date, not less than 19.7 MTPA of LNG from the Project, being the aggregate ACQ under all Qualifying LNG SPAs then in effect (except the Excess Capacity LNG SPAs); provided that (i) following the full payment of the required amount upon any LNG SPA Mandatory Prepayment, the Base Committed Quantity will be equal to the aggregate ACQ under the Qualifying LNG SPAs used to calculate the amount of Senior Debt that the Borrower is not required to repay upon an LNG SPA Prepayment Event under Section 3.4(a)(iii) (Mandatory Prepayments –LNG SPA Prepayment Events) of the Common Terms Agreement and (ii) to the extent that any other LNG SPA becomes a Qualifying LNG SPA or an existing Qualifying LNG SPA is amended to adjust the quantity of LNG contracted to be sold thereunder, the Base Committed Quantity will be equal to the aggregate ACQ under the Qualifying LNG SPAs as at such time.

 

-192-

Plaquemines – Amended & Restated Common Terms Agreement


Basis Swap” means a commodity derivative contract that is cash-settled based on the difference between: (a) the price of natural gas at one particular pricing point and (b) the price of natural gas at a different delivery location or pricing point.

Bcf” means billions of cubic feet.

Beneficial Ownership Certification” means a certification regarding beneficial ownership as required by the Beneficial Ownership Regulation.

Beneficial Ownership Regulation” 31 C.F.R. § 1010.230. “BHES” means Baker Hughes Energy Services LLC.

Borrower” means Venture Global Plaquemines LNG, LLC, a limited liability company organized under the laws of the State of Delaware. The Borrower is also referred to as the “Company” under the Common Security and Account Agreement and the “Mortgagor” under the Mortgage.

Bridge Lease Agreement” means the Bridge Lease Agreement, dated as of October 7, 2021, by and between the Borrower and Mammoet, as supplemented by the Limited Procurement Order, dated as of November 10, 2021, and as further supplemented by the Mobilization Notice, dated as of February 28, 2022, issued by the Borrower.

Bridge Loan” means the loans outstanding under that certain Credit and Guaranty Agreement, dated as of November 4, 2021, by and among the Borrower, as borrower, the Guarantor, as guarantor, the lenders party thereto and ING Capital LLC, as administrative agent, as may be amended, amended and restated, modified or supplemented from time to time.

Btu” means the amount of heat required to raise the temperature of one avoirdupois pound of pure water from fifty-nine degrees (59°) Fahrenheit to sixty degrees (60°) Fahrenheit at a pressure of fourteen point six nine six (14.696) pounds per square inch absolute (psia).

Business Day” means a day (other than a Saturday or Sunday) on which banks are generally authorized to be open for business under the laws of the State of New York.

Business Interruption Insurance Proceeds” means all proceeds of any insurance policies required pursuant to the Schedule of Minimum Insurance or otherwise obtained with respect to the Obligors or the Project Facilities insuring the Obligors against business interruption or delayed start-up.

 

-193-

Plaquemines – Amended & Restated Common Terms Agreement


Capital Lease” means any lease of (or other arrangement conveying the right to use) real or personal property, or a combination thereof, which obligations are required to be classified and accounted for as capital leases on a balance sheet under GAAP.

Cash Flow” means, with respect to any period, all funds received or, as applicable in the relevant context, projected to be received by the Obligors during such period, without duplication, including:

 

  (a)

amounts received by the Borrower under the LNG SPAs (including in respect of Supplemental Quantities sold by the Borrower as permitted under Section 8.4 (Sale of Supplemental Quantity) and in respect of quantities of LNG sold by the Borrower prior to the Project Phase 2 Completion Date as permitted under Section 8.5 (Sale of Pre-Completion Quantities));

 

  (b)

earnings on funds held in the Secured Accounts (excluding interest and investment earnings that accrue on the amounts on deposit in any of the Senior Facilities Debt Service Reserve Account or any account established to prefund interest on any Senior Debt, if any, in any case, that are not transferred to the Revenue Account pursuant to the Common Security and Account Agreement);

 

  (c)

any amounts deposited in the Insurance/Condemnation Proceeds Account to the extent applied to the payment of Operation and Maintenance Expenses or Project Costs in accordance with Article 5 (Insurance and Condemnation Proceeds and Performance Liquidated Damages) of the Common Security and Account Agreement;

 

  (d)

all cash paid to the Obligors during such period as Business Interruption Insurance Proceeds;

 

  (e)

proceeds from the transfer, sale or disposition of assets or rights of the Obligors in the ordinary course of business in accordance with Section 12.17 (Sale of Project Property) of the Common Terms Agreement (other than as set forth in sub-clause (6) below) to the extent such proceeds have been or will be used to pay Operation and Maintenance Expenses;

 

  (f)

amounts paid to each Obligor under any Material Project Agreement;

 

  (g)

amounts received by each Obligor under Permitted Hedging Instruments other than in respect of interest rates;

 

-194-

Plaquemines – Amended & Restated Common Terms Agreement


  (h)

with respect to the calculation of the Historical DSCR for any purpose other than such calculation under Section 11 (Restricted Payments) of the Common Terms Agreement, and for any period, all cash paid to the Borrower during the applicable period from any direct or indirect owner of the Borrower by way of Equity Funding (other than any Equity Contributions) (in each case as otherwise permitted pursuant to the terms of the Finance Documents) in accordance with Section 12.25(b) (Historical DSCR); and

 

  (i)

with respect to the calculation of Fixed Projected DSCR for any purpose other than such calculation under Section 11 (Restricted Payments) of the Common Terms Agreement, and for any period, any cash projected to be on deposit in the Secured Accounts at the commencement of such period as a result of a restriction on the making of Restricted Payments applicable prior to such period (without double counting any other amounts of Cash Flow taken into account in the calculation of the Fixed Projected DSCR);

but excluding, in each case:

 

  (1)

all amounts required to be deposited in the Insurance/Condemnation Proceeds Account used to reimburse Equity Funding;

 

  (2)

all proceeds of Senior Debt that are used to reimburse Drawstop Equity Contributions;

 

  (3)

proceeds of the final Advance on the Project Phase 2 Completion Date;

 

  (4)

the proceeds of the Project Phase 2 Completion Date Distribution;

 

  (5)

proceeds of third-party liability insurance;

 

  (6)

proceeds of the sale of assets permitted by Section 12.17(b) or (k) (Sale of Project Property) of the Common Terms Agreement unless and until applied to procure a replacement for such assets;

 

  (7)

proceeds of Senior Debt and other Indebtedness (and corresponding amounts received by the Obligors pursuant to any guarantees) permitted by Section 12.14 (Limitation on Indebtedness) of the Common Terms Agreement other than amounts received under Permitted Hedging Instruments included under clause (g) above;

 

  (8)

except as provided in clause (h) above, Equity Funding received from the Sponsor or any direct or indirect holders of equity interests of the Borrower; and

 

  (9)

any cash deposited into the Additional Proceeds Prepayment Account.

 

-195-

Plaquemines – Amended & Restated Common Terms Agreement


Cash Flow Available for Debt Service” means, for each applicable measurement period, the amount equal to (a) Cash Flow for such period (provided that, for any period prior to the Project Phase 2 Completion Date, such Cash Flow shall be limited to Cash Flow from the Phase 1 Project Facilities) minus (b) Operation and Maintenance Expenses for such period; provided that Operation and Maintenance Expenses included in the calculation of Historical DSCR and Fixed Projected DSCR will exclude (i) that portion of Operation and Maintenance Expenses arising with respect to the Phase 2 LNG Facility prior to the Project Phase 2 Completion Date that are Project Costs and (ii) Operation and Maintenance Expenses arising (A) with respect to the Phase 1 Project Facilities, from and after the Project Phase 1 Completion Date, Permitted Completion Costs in respect of the Phase 1 Project Facilities, and (B) with respect to the Phase 2 LNG Facility, from and after the Project Phase 2 Completion Date, Permitted Completion Costs, in each case for purposes of clauses (ii)(A) and (B), for which sufficient reserves are on deposit in the Construction Account or Completion Reserve Account, as applicable; provided further that, for any period prior to the Project Phase 2 Completion Date, for purposes of calculating the Fixed Projected DSCR, such Cash Flow Available for Debt Service shall be calculated solely to reflect (A) the Fixed Facility Charge under each of the Qualifying LNG SPAs with respect to the Phase 1 LNG Facility then in effect, (B) expected interest and investment earnings paid to the Obligors during such period, (C) amounts expected to be paid to the Obligors during such period as Business Interruption Insurance Proceeds with respect to the Phase 1 LNG Facility and (D) the fixed expenses that could reasonably be expected to be incurred by the Obligors if the Phase 1 Material Project Counterparties were not lifting any cargoes under the Qualifying LNG SPAs with respect to the Phase 1 LNG Facility then in effect.

Catastrophic Casualty Event” means any Event of Loss where Insurance Proceeds or Condemnation Proceeds are received in an aggregate amount for a single loss or related series of losses exceeding $1 billion.

CB&I” means CB&I LLC.

CCRA Consultant” means Lummus Consultants International LLC.

CERCLA” means the Comprehensive Environmental Response, Compensation and Liability Act (42 U.S.C. section 9604, et seq.) and rules and regulations issued thereunder.

Cessation Notice” has the meaning given in Section 15.3 (Cessation of Loan Facility Declared Default) of the Common Terms Agreement.

 

-196-

Plaquemines – Amended & Restated Common Terms Agreement


Change in Law” means the occurrence, with respect to any Initial Senior Creditor, after the Initial Closing Date and with respect to any Incremental Senior Creditor, after the Upsize Closing Date, of any of the following:

  (a)

the adoption or taking effect of any law;

 

  (b)

any change in any law or in the administration, interpretation, implementation or application thereof by any Governmental Authority; or

 

  (c)

the making or issuance of any request, rule, guideline or directive (whether or not having the force of law) by any Governmental Authority;

provided that, notwithstanding anything herein to the contrary, (x) the Dodd-Frank Wall Street Reform and Consumer Protection Act and all requests, rules, guidelines or directives thereunder or issued in connection therewith and (y) all requests, rules, guidelines or directives promulgated by the Bank for International Settlements, the Basel Committee on Banking Supervision (or any successor or similar authority) or the United States or foreign regulatory authorities, in each case pursuant to Basel III, shall in each case be deemed to be a “Change in Law”, regardless of the date enacted, adopted or issued.

Change of Control” means

 

  (a)

prior to the Project Phase 2 Completion Date, the Sponsor and any Approved Owners, collectively, shall cease to, directly or indirectly, maintain (i) voting or managerial control of the Borrower or the Guarantor or (ii) 75% of the economic interest in the Borrower or the Guarantor; provided that, (A) any Person to whom any portion of the remaining 25% of such economic interest is transferred shall satisfy the requirements for a Qualified Owner set forth in clauses (b), (c) and (d) of the definition thereof, and (B) the proceeds of any such transfer shall, until the Project Phase 2 Completion Date be segregated (or deposited into the Construction Account) and available solely to pay Project Costs when due and payable; or

 

  (b)

after the Project Phase 2 Completion Date, (i) the Sponsor, any Approved Owners and any Qualified Owners, collectively, shall cease to, directly or indirectly, maintain voting or managerial control of the Borrower or the Guarantor or (ii) the Sponsor, any Approved Owners and any Qualified Owners, collectively, shall cease to, directly or indirectly, maintain more than 50% of the economic interest in the Borrower or the Guarantor; or

 

  (c)

at any time, the Pledgor shall cease to directly maintain 100% of the voting and economic interests in the Borrower or the Guarantor.

Change Order” has the meaning given in the Material Construction Contract.

Chevron” means Chevron U.S.A. Inc.

China Gas” means China Gas Hongda Energy Trading Co., LTD.

 

-197-

Plaquemines – Amended & Restated Common Terms Agreement


CNOOC” means CNOOC Gas and Power Singapore Trading & Marketing Pte. Ltd.

Code” means the Internal Revenue Code of 1986, as amended.

Collateral” means any property right or interest subject to a Security Interest.

Collateral Agency Fee Letter” means the fee letter dated as of the Initial Closing Date entered into between the Borrower, the Guarantor and the Collateral Agent in respect of the fees payable to the Collateral Agent in respect of its services to be performed as more fully described in the Common Security and Account Agreement and the other Finance Documents.

Collateral Agent” means the trustee named under the Common Security and Account Agreement as collateral agent for the Secured Parties.

Collateral Parties” means the Obligors and Pledgor, and “Collateral Party” shall have a corresponding meaning.

Collateral Records” means books, records, ledger cards, files, correspondence, customer lists, supplier lists, blueprints, technical specifications, manuals, computer software and related documentation, computer printouts, tapes, disks and other electronic storage media and related data processing software and similar items that at any time evidence or contain information relating to any of the Collateral or are otherwise necessary or helpful in the collection thereof or realization thereupon.

Commercial Operation Date” has the meaning given in the applicable LNG SPA.

Commodity Exchange Act” means the Commodity Exchange Act, as amended (7 U.S.C. § 1 et seq.).

Common Collateral” means any property right or interest subject to a Security Interest granted or purported to be created by or pursuant to Section 3.2(a) (Security Interests to be Granted by the Obligors – Pledge of Pledged Collateral), Section 3.2(b) (Security Interests to be Granted by the Obligors – Security Interests – General) or Section 3.2(e) (Security Interests to be Granted by the Obligors – Real Property) of the Common Security and Account Agreement or pursuant to any Security Document other than (a) the Senior Facilities Debt Service Reserve Account and the funds on deposit therein and (b) any Additional Debt Service Reserve Account and the funds on deposit therein, in each case, which shall be applied in accordance with Section 7.7 (Sharing) of the Common Security and Accounts Agreement.

 

-198-

Plaquemines – Amended & Restated Common Terms Agreement


Common Security and Account Agreement” means the Amended and Restated Common Security and Account Agreement, dated as of the Upsize Closing Date, among the Borrower, the Guarantor, each Senior Creditor Group Representative on its own behalf and on behalf of the relevant Senior Creditor Group, the Intercreditor Agent, the Collateral Agent and the Account Bank.

Common Terms Agreement” means the Amended and Restated Common Terms Agreement, dated as of the Upsize Closing Date, among the Borrower, the Guarantor, the Credit Facility Agent and each other Facility Agent on behalf of its respective Facility Lenders, and the Intercreditor Agent providing common representations, warranties, undertakings and events of default. For the avoidance of doubt, (i) any reference to an individual Senior Debt Instrument which is a Facility Agreement shall be deemed to include reference to the Common Terms Agreement; and (ii) references to an Indenture, or to any individual Senior Debt Instrument that is an Indenture, shall be deemed not to include reference to the Common Terms Agreement.

Company” means Venture Global Plaquemines LNG, LLC, a limited liability company organized under the laws of the State of Delaware. The Company is also referred to as the “Borrower” in certain Finance Documents, the “Mortgagor” in the Mortgage, and the “Issuer” in other Finance Documents.

Completion Reserve Account” means the account described in Section 4.3(a)(xiv) (Accounts) of the Common Security and Account Agreement.

Condemnation Proceeds” means any amounts and proceeds of any kind (including instruments) payable in respect of any Event of Taking.

Confidential Information” means all information received from any Obligor, the Pledgor, the Sponsor, any Approved Owner or any of their respective Affiliates or on their behalf relating to any of such entities, their respective businesses, the Project Facilities, the Material Project Agreements or the Development.

Connection Income Taxes” means Other Connection Taxes that are imposed on or measured by net income (however denominated) or that are franchise Taxes or branch profits Taxes.

Constitutional Documents” means certificates of formation, limited liability company agreements, partnership agreements, certificates of incorporation, bylaws or any similar entity organizational or constitutive document.

Construction Account” is the account described in Section 4.3(a)(v) (Accounts) of the Common Security and Account Agreement.

 

-199-

Plaquemines – Amended & Restated Common Terms Agreement


Construction Budget and Schedule” means (a) the budget delivered pursuant to Section 4.1(g)(i) (Conditions to Initial Closing Date and Initial Advance – Project Development) of the Common Terms Agreement as updated and delivered pursuant to Section 4.2(g)(i) (Conditions to Upsize Closing Date – Project Development) of the Common Terms Agreement (which shall be substantially in the form of budget attached as Schedule D-1 (Construction Budget and ScheduleConstruction Budget) to the Common Terms Agreement) and (b) the schedule delivered pursuant to Section 4.1(g)(i) (Conditions to Initial Closing Date and Initial Advance – Project Development) of the Common Terms Agreement as updated and delivered pursuant to Section 4.2(g)(i) (Conditions to Upsize Closing Date – Project Development) of the Common Terms Agreement (which shall be substantially in the form of schedule attached as Schedule D-2 (Construction Budget and Schedule – Construction Schedule)).

Construction Contractors” means the Phase 1 Construction Contractors and the Phase 2 Construction Contractors.

Construction Dock and Marine Offloading Facilities Construction Agreement” means that certain Construction Agreement Relating to Construction Dock and Marine Offloading Facilities, dated as of August 19, 2020, by and between the Borrower and Weeks-Massman, as amended by Amendment No. 1 to Construction Agreement (Construction Dock and Marine Offloading Facilities), dated as of July 1, 2021, Amendment No. 2 to Construction Agreement (Construction Dock and Marine Offloading Facilities), dated as of July 8, 2021, and Amendment No. 3 to Construction Agreement (Construction Dock and Marine Offloading Facilities), dated as of October 8, 2021, Amendment No. 4 to Construction Agreement (Construction Dock and Marine Offloading Facilities), dated as of August 5, 2022, Amendment No. 5 to Construction Agreement (Construction Dock and Marine Offloading Facilities), dated as of September 1, 2022, Change Order No. 1, dated as of May 13, 2022, Change Order No. 2, dated as of August 5, 2022, Change Order No. 3, dated as of October 25, 2022, Change Order No. 4, dated as of March 2, 2023, and as supplemented by Anticipated LNTP, dated as of September 24, 2020, issued by the Borrower, Limited Notice to Proceed No. 2 (Construction Dock and Marine Offloading Facilities), dated as of July 8, 2021, by and among the Borrower and Weeks-Massman, Notice to Proceed, dated as of November 5, 2021, issued by the Borrower.

Consultants” has the meaning given in Section 13.1 (Appointment of Consultants) of the Common Terms Agreement.

Contingency Reserve Account” is the account described in Section 4.3(a)(ix) (Accounts) of the Common Security and Account Agreement.

Contingency Reserve Amount” means (a) prior to the Project Phase 1 Completion Date, an amount equal to $[***], and (b) on and after the Project Phase 1 Completion Date and before the Project Phase 2 Completion Date, an amount equal to $[***].

 

-200-

Plaquemines – Amended & Restated Common Terms Agreement


Contingency Reserve Term Loan Commitment” has the meaning provided in the Credit Facility Agreement.

Continuing” (including, with its corresponding meaning, the terms “Continuance” and “Continuation”) means:

 

  (a)

with respect to any Loan Facility Declared Default, Indenture Declared Default or other comparable event of default or termination event under any other Senior Debt Instrument or Permitted Hedging Instrument, that such event of default or termination event has occurred without the need for declaration, or been declared by required Senior Creditor action, in each case in conformity with the requirements of the Common Terms Agreement or such other Senior Debt Instrument or Permitted Hedging Instrument, as the case may be, and no Cessation Notice or similar notice shall have been given with respect thereto;

 

  (b)

with respect to any Unmatured Loan Facility Event of Default, Unmatured Indenture Event of Default or other unmatured default or termination event under any other Senior Debt Instrument or Permitted Hedging Instrument, that such unmatured default or termination event has occurred and has not been waived or cured; and

 

  (c)

with respect to any Loan Facility Event of Default, Indenture Event of Default or other event of default or termination event under any other Senior Debt Instrument or Permitted Hedging Instrument, that such event of default or termination event has occurred and has not been declared, waived or cured.

Contract Sales Price” has the meaning given in the applicable LNG SPA.

Control” of a Person means the power to direct the management and policies of that Person, directly or indirectly, whether through the ownership of voting securities, by operation of law, by contract (including pursuant to a partnership or similar agreement) or otherwise; and the terms “Controlling” and “Controlled” have corresponding meanings to the foregoing.

Control Agreements” means any Deposit Account Control Agreement or Securities Account Control Agreement entered into by and among the Borrower or Guarantor, the Collateral Agent and City National Bank or a Third Party Account Bank, with respect to a Local Account or a Third Party Investment Account in accordance with the Common Security and Account Agreement (Details of Initial Accounts).

Controlling Claimholders” means Senior Creditor Group Representatives representing a Majority in Interest of the Senior Creditors.

 

-201-

Plaquemines – Amended & Restated Common Terms Agreement


Coordinating Lead Arranger” has the meaning given in Exhibit A (Definitions) to the Credit Facility Agreement.

Copyright Licenses” means any and all agreements, licenses and covenants providing for the granting of any right in or to any Copyright or otherwise providing for a covenant not to sue for infringement or other violation of any Copyright (whether an Obligor is licensee or licensor thereunder) including each agreement required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Copyright Licenses” (as such schedule may be amended or supplemented from time to time).

Copyrights” means all United States, and foreign copyrights (whether or not the underlying works of authorship have been published), including copyrights in software and all rights in and to databases, all designs (including but not limited to industrial designs, Protected Designs within the meaning of 17 U.S.C. 1301 et. seq. and Community designs), and all Mask Works (as defined under 17 U.S.C. 901 of the US Copyright Act), whether registered or unregistered, as well as all moral rights, reversionary interests, and termination rights, and, with respect to any and all of the foregoing:

 

  (a)

all registrations and applications therefor including the registrations and applications required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Copyrights” (as such schedule may be amended or supplemented from time to time);

 

  (b)

all extensions, renewals and restorations thereof;

 

  (c)

all rights to sue or otherwise recover for any past, present and future infringement or other violation thereof;

 

  (d)

all proceeds of the foregoing, including license fees, royalties, income, payments, claims, damages and proceeds of suit now or hereafter due and/or payable with respect thereto; and

 

  (e)

all other rights of any kind accruing thereunder or pertaining thereto throughout the world.

CP Satisfaction Date” has the meaning given in the applicable LNG SPA.

Credit Facility Agency Fee Letter” means the fee letter dated as of the Initial Closing Date entered into between the Borrower, the Guarantor and the Credit Facility Agent in respect of the fees payable to the Credit Facility Agent in respect of its services to be performed as more fully described in the Credit Facility Agreement and the other Finance Documents.

 

-202-

Plaquemines – Amended & Restated Common Terms Agreement


Credit Facility Agent” means the facility agent under the Credit Facility Agreement.

Credit Facility Agreement” means the Amended and Restated Credit Facility Agreement, dated as of the Upsize Closing Date, by and among the Borrower, the Guarantor, the Credit Facility Lender Parties party thereto from time to time, the Credit Facility Agent and, solely for purposes of Section 3.06 thereof, the Collateral Agent.

Credit Facility Lender Parties” means the Credit Facility Lenders and the Issuing Banks under the Credit Facility Agreement.

Credit Facility Lenders” means the “Lenders” under the Credit Facility Agreement.

Credit Facility Secured Parties” has the meaning given in Exhibit A (Definitions) to the Credit Facility Agreement.

CTA Payment Date” means (a) each Quarterly Payment Date, (b) the date for payment of Senior Debt Obligations (including payment dates for the payment of interest) under or pursuant to any Facility Agreement or Permitted Hedging Instrument, including the Common Terms Agreement and (c) the scheduled Final Maturity Date under each Facility Agreement.

Debt Domain Website” has the meaning given in Section 12.7(b) (Notices) of the Common Security and Account Agreement.

Debt Service” means, for any period, the sum computed without duplication, of the following: (a) all amounts payable by the Borrower in respect of scheduled principal of indebtedness during such period in respect of Senior Debt Obligations, plus (b) interest on Senior Debt Obligations (taking into account Permitted Hedging Instruments) scheduled to become due and payable (or for purposes of the Historical DSCR, Fixed Projected DSCR, accrued or paid) during such period, plus (c) all other commitment fees, agency fees, trustee fees or other administrative fees (other than upfront fees, arranging fees, underwriting fees or similar fees) payable in connection with the Senior Debt Obligations; provided, that prior to the Project Phase 2 Completion Date, Debt Service shall be calculated taking into account only the interest and fees payable in respect of the Initial Term Loan Amount (as defined in the Credit Facility Agreement) (and not all Term Loans more broadly), and taking into account amortization in respect of all Term Loans.

Debt Service Reserve Account” means the Senior Facilities Debt Service Reserve Account and each Additional Debt Service Reserve Account.

 

-203-

Plaquemines – Amended & Restated Common Terms Agreement


Decision” means any notice, consent, decision, approval, instruction, judgment, direction, objection or Modification.

Declared Event of Default” means an Event of Default that has been declared or is otherwise deemed to have been declared by a Senior Creditor Group Representative under its Senior Debt Instrument (acting on behalf of the Senior Creditors under, and in accordance with, such Senior Debt Instrument) or otherwise is deemed to have been declared in accordance with the terms of the relevant Senior Debt Instrument.

Default Rate” means a rate per annum equal to the rate that would otherwise be applicable plus 2%, or if there is no applicable interest rate, a rate per annum equal to the highest interest rate applicable to any then-outstanding Senior Debt plus 2%.

Defaulting Lender”, with respect to a Facility Agreement, has the meaning given in such Facility Agreement.

Delay Liquidated Damages” means any liquidated damages that are required to be paid to an Obligor under any Material Construction Contract by any Construction Contractor for or on account of any delay in the delivery of equipment and materials, completion of construction activities or in the completion of one or more Performance Tests.

Development” means the Project Phase 1 Development and the Project Phase 2 Development. “Develop” and “Developed” shall have corresponding meanings.

Development Expenditures” means, for any period, the aggregate amount of all expenditures of the Obligors payable during such period that, in accordance with GAAP, are or should be included in “purchase of property, plant and equipment” or similar items reflected in the consolidated statement of cash flows of the Obligors.

DIP Financing” has the meaning given in Section 10.5(b) (Certain Agreements with Respect to Bankruptcy) of the Common Security and Account Agreement.

DIP Financing Liens” has the meaning given in Section 10.5(b)(ii) (Certain Agreements with Respect to Bankruptcy) of the Common Security and Account Agreement.

DIP Lenders” has the meaning given in Section 10.5(b) (Certain Agreements with Respect to Bankruptcy) of the Common Security and Account Agreement.

Direct Agreements” means:

 

  (a)

Consent to Collateral Assignment, dated as of the Initial Closing Date, by and among PGNIG, the Borrower and the Collateral Agent;

 

-204-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

Consent to Collateral Assignment, dated as of the Initial Closing Date, by and among EDF, the Borrower and the Collateral Agent;

 

  (c)

Direct Agreement (Buyer), dated as of the Initial Closing Date, by and among Sinopec, the Borrower and the Collateral Agent;

 

  (d)

Direct Agreement (Buyer), dated as of the Initial Closing Date, by and among Sinopec, the Borrower and the Collateral Agent;

 

  (e)

Notice of Acknowledgement and Consent, dated as of the Initial Closing Date, by and among CNOOC, the Borrower and the Collateral Agent;

 

  (f)

Consent to Collateral Assignment, dated as of the Initial Closing Date, by and among Shell, the Borrower and the Collateral Agent;

 

  (g)

Direct Agreement, dated as of the Initial Closing Date, by and among Venture Global Commodities, LLC, the Borrower and the Collateral Agent;

 

  (h)

Notice of Acknowledgement and Consent, dated as of the Initial Closing Date, by and among CNOOC Gas and Power Group Co., Ltd., the Borrower and the Collateral Agent;

 

  (i)

Consent to Collateral Assignment, dated as of the Initial Closing Date, by and among Shell USA, Inc, the Borrower and the Collateral Agent;

 

  (j)

Consent and Agreement, dated as of the Initial Closing Date, by and among the EPC Contractor, the Borrower and the Collateral Agent;

 

  (k)

Consent and Agreement, dated as of the Initial Closing Date, by and among KBR, Inc., the Borrower and the Collateral Agent;

 

  (l)

Consent and Agreement, dated as of the Initial Closing Date, by and among Zachry Holdings, Inc., the Borrower and the Collateral Agent;

 

  (m)

Consent and Agreement, dated as of the Initial Closing Date, by and among CB&I, McDermott International, Ltd., the Borrower and the Collateral Agent;

 

  (n)

Consent and Agreement, dated as of the Initial Closing Date, by and among Weeks-Massman, Weeks Marine Inc., Massman Construction Co., the Borrower and the Collateral Agent;

 

  (o)

Consent and Agreement, dated as of the Initial Closing Date, by and among Sunland Construction, Inc., the Guarantor and the Collateral Agent;

 

-205-

Plaquemines – Amended & Restated Common Terms Agreement


  (p)

Consent and Agreement, dated as of the Initial Closing Date, by and among Gulf Interstate Engineering Company, the Guarantor and the Collateral Agent;

 

  (q)

Consent to Assignment and Agreement, dated as of the Initial Closing Date, by and among BHES, the Borrower and the Collateral Agent;

 

  (r)

Consent to Assignment and Agreement, dated as of the Initial Closing Date, by and among Baker Hughes Holdings LLC, the Borrower and the Collateral Agent;

 

  (s)

Consent to Assignment and Agreement, dated as of the Initial Closing Date, by and among General Electric Company, the Borrower and the Collateral Agent;

 

  (t)

Consent to Assignment and Agreement, dated as of the Initial Closing Date, by and among UOP, the Borrower and the Collateral Agent;

 

  (u)

Consent to Assignment and Agreement, dated as of the Initial Closing Date, by and among Honeywell International Inc., the Borrower and the Collateral Agent;

 

  (v)

Consent to Assignment, dated as of the Initial Closing Date, by and among Texas Eastern Transmission, LP, the Guarantor and the Collateral Agent;

 

  (w)

Consent to Assignment, dated as of the Initial Closing Date, by and among Texas Eastern Transmission, LP, the Borrower and the Collateral Agent;

 

  (x)

Consent and Agreement, dated as of the Initial Closing Date, by and among Tennessee Gas Pipeline Company, L.L.C., the Borrower, the Guarantor and the Collateral Agent;

 

  (y)

Consent and Agreement, dated as of the Initial Closing Date, by and among Columbia Gulf Transmission, LLC, the Borrower and the Collateral Agent;

 

  (z)

Consent and Agreement, dated as of the Initial Closing Date, by and among Mammoet, the Borrower and the Collateral Agent;

 

  (aa)

Direct Agreement, dated as of the Initial Closing Date, by and between the Manager and the Collateral Agent and acknowledged and agreed to by the Borrower;

 

  (bb)

Direct Agreement, dated as of the Initial Closing Date, by and between the Manager and the Collateral Agent, and acknowledged and agreed to by the Guarantor;

 

-206-

Plaquemines – Amended & Restated Common Terms Agreement


  (cc)

Direct Agreement, dated as of the Initial Closing Date, by and between the Pipeline Operator and the Collateral Agent, and acknowledged and agreed to by the Guarantor;

 

  (dd)

Direct Agreement, dated as of the Initial Closing Date, by and between the Operator and the Collateral Agent, and acknowledged and agreed to by the Borrower;

 

  (ee)

Consent to Collateral Assignment, dated as of the Upsize Closing Date, by and among ENBW, the Borrower and the Collateral Agent;

 

  (ff)

Consent to Collateral Assignment, dated as of the Upsize Closing Date, by and among NFE, the Borrower and the Collateral Agent;

 

  (gg)

Consent to Collateral Assignment, dated as of the Upsize Closing Date, by and among Exxon, the Borrower and the Collateral Agent;

 

  (hh)

Direct Agreement, dated as of the Upsize Closing Date, by and among Petronas, the Borrower and the Collateral Agent;

 

  (ii)

Consent to Collateral Assignment, dated as of the Upsize Closing Date, by and among Chevron, the Borrower and the Collateral Agent;

 

  (jj)

Direct Agreement, dated as of the Upsize Closing Date, by and among Venture Global Commodities, LLC, the Borrower and the Collateral Agent;

 

  (kk)

Consent to Collateral Assignment, dated as of the Upsize Closing Date, by and among New Fortress Energy Inc., the Borrower and the Collateral Agent;

 

  (ll)

Direct Agreement (Buyer), dated as of the Upsize Closing Date, by and among China Gas, the Borrower and the Collateral Agent;

 

  (mm)

Notice of Acknowledgement and Consent, dated as of the Upsize Closing Date, by and among China Gas Holdings Limited, the Borrower and the Collateral Agent;

 

  (nn)

Consent to Collateral Assignment, dated as of the Upsize Closing Date, by and among Excelerate, the Borrower and the Collateral Agent;

 

  (oo)

Consent to Collateral Assignment, dated as of the Upsize Closing Date, by and among Excelerate Energy Limited Partnership, the Borrower and the Collateral Agent;

 

  (pp)

Consent and Agreement, dated as of the Upsize Closing Date, by and among the EPC Contractor, the Borrower and the Collateral Agent;

 

-207-

Plaquemines – Amended & Restated Common Terms Agreement


  (qq)

Consent and Agreement, dated as of the Upsize Closing Date, by and among KBR, Inc., the Borrower and the Collateral Agent;

 

  (rr)

Consent and Agreement, dated as of the Upsize Closing Date, by and among Zachry Holdings, Inc., the Borrower and the Collateral Agent;

 

  (ss)

Consent and Agreement, dated as of the Upsize Closing Date, by and among CB&I, the Borrower and the Collateral Agent;

 

  (tt)

Consent and Agreement, dated as of the Upsize Closing Date, by and among Weeks-Massman, Weeks Marine Inc., Massman Construction Co., the Borrower and the Collateral Agent;

 

  (uu)

Consent to Assignment and Agreement, dated as of the Upsize Closing Date, by and among BHES, the Borrower and the Collateral Agent;

 

  (vv)

Consent to Assignment and Agreement, dated as of the Upsize Closing Date, by and among Baker Hughes Holdings LLC, the Borrower and the Collateral Agent;

 

  (ww)

Consent to Assignment and Agreement, dated as of the Upsize Closing Date, by and among UOP, the Borrower and the Collateral Agent;

 

  (xx)

Consent to Assignment and Agreement, dated as of the Upsize Closing Date, by and among Honeywell International Inc., the Borrower and the Collateral Agent;

 

  (yy)

Direct Agreement, dated as of the Upsize Closing Date, by and among Plaquemines Tug Services, LLC, the Borrower and the Collateral Agent; and

 

  (zz)

the agreements described in Section 3.4 (Direct Agreements) of the Common Security and Account Agreement.

Disbursement Account” means the Loan Facility Disbursement Accounts and Senior Note Disbursement Accounts required to be established pursuant to Section 4.3(a)(i)-(ii) (Accounts) of the Common Security and Account Agreement.

Disbursement Endorsement” means endorsement(s) to the Title Policy (dated not earlier than two Business Days prior to the date of the requested Advance, as applicable) substantially in the form of the ALTA 33-06 Endorsement attached to as Schedule W (Form of Disbursement Endorsement) to the Common Terms Agreement (which has been paired with the ALTA 32-06 Endorsement attached to the Title Policy).

 

-208-

Plaquemines – Amended & Restated Common Terms Agreement


Disbursement Request” means a drawdown notice or request for issuance of letter(s) of credit, as applicable, substantially in the form set forth in Schedule B-1 (Disbursement Request Form (Term Loans)), Schedule B-2 (Disbursement Request Form (Working Capital Loans)) or Schedule B-3 (Issuance Request Form (Letters of Credit)) to the Common Terms Agreement (or equivalent under another Senior Debt Instrument), given by the Borrower requesting an Advance with respect to a Loan in accordance with the terms of Section 2.3 (Loan Disbursement and Letter of Credit Issuance Procedures) of the Common Terms Agreement and/or the applicable Facility Agreement or a request for issuance of letter(s) of credit in accordance with the terms of the applicable Facility Agreement.

Discharge Date” means:

 

  (a)

with respect to the Senior Debt Obligations under a Senior Debt Instrument, the date on which such Senior Debt Obligations thereunder shall have been unconditionally paid or discharged in full in US Dollars (other than Senior Debt Obligations thereunder that by their terms survive and with respect to which no claim has been made by the applicable Senior Creditor), the Senior Debt Commitments thereunder shall have been terminated, expired or been reduced to zero and all letters of credit thereunder (if any) shall have been terminated or collateralized in accordance with the provisions of such Senior Debt Instrument;

 

  (b)

with respect to the Senior Debt Obligations under a Permitted Senior Debt Hedging Instrument, the date on which such Senior Debt Obligations thereunder shall have been unconditionally paid or discharged in full in US Dollars (other than Senior Debt Obligations thereunder that by their terms survive and with respect to which no claim has been made by the applicable Senior Creditor) and all transactions under such Permitted Senior Debt Hedging Instrument shall have terminated or expired; and

 

  (c)

with respect to all Senior Debt Obligations, collectively, the date on which each of the above shall have occurred with respect to each then-existing Senior Debt Instrument and Permitted Senior Debt Hedging Instrument and any other Senior Debt Obligations owing to the Intercreditor Agent, Facility Agents, Collateral Agent or other Secured Parties shall have been unconditionally paid or discharged in full in US Dollars (other than Senior Debt Obligations that by their terms survive and with respect to which no claim has been made by the applicable Secured Party).

Disqualified Advisor” means (a) unless otherwise consented to by the Borrower in writing (including email) any Person set forth by the Borrower on Schedule Z (Disqualified Advisors) of the Common Terms Agreement as of the Upsize Closing Date (the “Disqualified Advisor List”), as updated from time to time by the Borrower by three Business Days’ prior written notice to the Intercreditor Agent

 

-209-

Plaquemines – Amended & Restated Common Terms Agreement


and each Facility Agent to add any counsel, consultants or other advisors of the Borrower or (b) any clearly identifiable (solely on the basis of its name or as identified by the Borrower to the Credit Facility Agent) Affiliate of the entities described in clause (a); provided, that any designation as a “Disqualified Advisor” shall not apply retroactively.

Disqualified Institution” means (a) any Person set forth by the Borrower on Schedule Y (Disqualified Institutions) of the Common Terms Agreement as of the Upsize Closing Date, as updated from time to time by the Borrower by three Business Days’ prior written notice to the Intercreditor Agent and each Facility Agent to add any competitor of any Obligor or (b) any clearly identifiable (solely on the basis of its name or as identified by the Borrower to the Intercreditor Agent) Affiliate of the entities described in clause (a), excluding any bona fide debt fund affiliate of such Person that is primarily engaged in, or advises funds or other investment vehicles that are engaged in, making, purchasing, holding, or otherwise investing in commercial loans, bonds, and similar extensions of credit or securities in the ordinary course of its business; provided that any designation as a “Disqualified Institution” shall not apply retroactively to any then current Credit Facility Lenders or any entity that has acquired an assignment or participation interest in any Term Loans or Working Capital Loans in accordance with and under the Credit Facility Agreement. The parties to this Agreement hereby acknowledge and agree that no Facility Agent shall be deemed to be in default under this Agreement or to have any duty or responsibility or to incur any liabilities, nor shall such Facility Agent have any duty, responsibility or liability to monitor or enforce assignments, participations or other actions in respect of Disqualified Institutions, or otherwise take (or omit to take) any action with respect thereto.

Distribution Account” is the account described in Section 4.3(a)(xv) (Accounts) of the Common Security and Account Agreement.

Documentation Bank” has the meaning set forth in the Credit Facility Agreement.

Documentation Bank Fee Letters” means the fee letter, dated as of the Initial Closing Date, entered into between the Borrower, the Guarantor and The Bank of Nova Scotia, Houston Branch in respect of the fees payable to The Bank of Nova Scotia, Houston Branch in respect of its services to be performed as Documentation Bank in respect of the Initial Closing Date (as more fully described in the Credit Facility Agreement and the other Finance Documents) and the fee letter, dated as of the Upsize Closing Date, entered into between the Borrower, the Guarantor, ING Capital LLC and The Bank of Nova Scotia, Houston Branch in respect of the fees payable to ING Capital LLC and The Bank of Nova Scotia, Houston Branch in respect of their respective services to be performed as Documentation Banks in respect of the Upsize Closing Date (as more fully described in the Credit Facility Agreement and the other Finance Documents).

 

-210-

Plaquemines – Amended & Restated Common Terms Agreement


DOE” means the US Department of Energy. “DOT” means the US Department of Transportation.

DPU” means Delivered at Place Unloaded as defined in Incoterms 2010.

DPU LNG SPA” means an LNG SPA on DPU terms, including shipping arrangements that are substantially consistent with those specified in Schedule BB (Shipping Agency Term Sheet).

DPU LNG SPA Quantity Restrictions” has the meaning given in Section 12.5(l) (Material Project Agreements).

Drawstop Equity Contributions” means contributions of cash equity made to Borrower during any period in which Borrower is unable to satisfy the conditions set forth in Section 4.3 (Conditions to Each Term Loan Advance) of this Agreement, which contributions shall not be required to be deposited into the Construction Account in accordance with the Common Security and Account Agreement. For the avoidance of doubt, no Equity Contribution shall be a Drawstop Equity Contribution.

DSCR” means Historical DSCR or Fixed Projected DSCR. “EDF” means Électricité de France, S.A.

EEA Financial Institution” means (a) any credit institution or investment firm established in any EEA Member Country that is subject to the supervision of an EEA Resolution Authority, (b) any entity established in an EEA Member Country that is a parent of an institution described in clause (a) of this definition, or (c) any financial institution established in an EEA Member Country that is a subsidiary of an institution described in clauses (a) or (b) of this definition and is subject to consolidated supervision with its parent.

EEA Member Country” means any of the member states of the European Union, Iceland, Liechtenstein, and Norway.

EEA Resolution Authority” means any public administrative authority or any Person entrusted with public administrative authority of any EEA Member Country (including any delegee) having responsibility for the resolution of any EEA Financial Institution.

ENBW” means ENBW Energie Baden-Württemberg AG.

Enforcement Action” has the meaning given in Section 16.1(a) (Facility Lender Remedies for Loan Facility Declared Events of Default – Enforcement Action) of the Common Terms Agreement.

 

-211-

Plaquemines – Amended & Restated Common Terms Agreement


Enforcement Proceeds Account” has the meaning given in Section 6.7(a) (Enforcement Proceeds Account) of the Common Security and Account Agreement.

Environmental Claim” means any administrative, regulatory or judicial action, suit, judgment or other legal action (collectively, a “claim”) by any Person alleging or asserting liability for investigatory costs, response, cleanup or other remedial costs, legal costs, environmental consulting costs, governmental environmental response costs, damages to natural resources or other property, personal injuries, fines or penalties arising out of (a) the presence, Release or threatened Release into the environment, of any Hazardous Material at any location, whether or not owned by the Person against whom such claim is made, or (b) any violation of any Environmental Law. The term “Environmental Claim” will include any claim by any Person or Governmental Authority for enforcement, cleanup, removal, response, remedial action or damages pursuant to any Environmental Law, and any claim by any third party seeking damages, contribution, indemnification, cost recovery, compensation or injunctive relief under any Environmental Law.

Environmental Consultant” means each of Environmental Resources Management, Inc. and Environmental Resources Management Southwest, Inc. or any independent replacement environmental consulting firm to be selected in accordance with Section 13.2 (Replacement and Fees) of the Common Terms Agreement.

Environmental Laws” means all federal, state, and local statutes, laws, regulations, rules, judgments (including all tort causes of action), orders or decrees, in each case as modified and supplemented and in effect from time to time concerning the regulation, use or protection of the environment, coastal resources, protected plant and animal species, human health and safety, Hazardous Materials, including exposure to or to Releases or threatened Releases of Hazardous Materials into the environment, including ambient air, soil, surface water, groundwater, wetlands, coastal waters, land or subsurface strata, or otherwise relating to the generation, manufacture, processing, distribution, use, treatment, storage, disposal, transport or handling of Hazardous Materials.

EPC Change in Law” means “Change in Law” as defined in each applicable Material Construction Contract.

EPC Contractor” means KZJV LLC.

Equator Principles” means the principles named “Equator Principles – A financial industry benchmark for determining, assessing and managing social and environmental risk in projects” adopted by various financing institutions in the form dated July 2020 and effective October 2020, available at: https://equator-principles.com/wp-content/uploads/2020/05/The-Equator-Principles-July-2020- v2.pdf.

 

-212-

Plaquemines – Amended & Restated Common Terms Agreement


Equity Contribution” means the amounts funded in accordance with Section 4.1(aa) (Conditions to Initial Closing Date and Initial Advance – Equity Funding Commitments and Minimum Funded Amount) and Section 4.2(y) (Conditions to Upsize Closing Date – Equity Funding Commitments and Minimum Funded Amount).

Equity Funding” means contributions made to the Borrower in the form of:

 

  (a)

equity funding from a direct or indirect shareholder (including the Equity Contribution);

 

  (b)

payment of Project Costs in respect of the Development prior to the Initial Closing Date to the extent such amounts were not funded with Bridge Loans or reimbursed with the proceeds of Bridge Loans;

 

  (c)

payment of Project Costs in respect of the Project Phase 2 Development prior to the Upsize Closing Date in the amount set forth in the certificate of the Independent Engineer delivered pursuant to Section 4.2(g)(vii) (Conditions to Upsize Closing Date – Project Development);

 

  (d)

Cash Flow applied or committed to be applied towards Project Costs prior to the Project Phase 2 Completion Date (including (i) Pre-Completion Revenues transferred from the Phase 1 Pre-Completion Revenues Account to the Construction Account or the Contingency Reserve Account in accordance with Section 4.5(b)(ii)(C) (Deposits and Withdrawals – Phase 1 Pre-Completion Revenues Account) of the Common Security and Account Agreement, (ii) Pre-Completion Revenues transferred from the Phase 2 Pre- Completion Revenues Account to the Construction Account or the Contingency Reserve Account in accordance with Section 4.5(c)(ii)(C) (Deposits and Withdrawals – Phase 2 Pre-Completion Revenues Account) of the Common Security and Account Agreement and (iii) on and following the Project Phase 1 Completion Date, proceeds on deposit in the Revenue Account at the eighth or eleventh level of priority in the waterfall in Section 4.7 (Cash Waterfall) of the Common Security and Account Agreement to the extent permitted by Section 4.7(a)(viii) (Cash Waterfall) or 4.7(a)(xi) (Cash Waterfall) of the Common Security and Account Agreement, as applicable, and, in each case, applied towards such Project Costs);

 

-213-

Plaquemines – Amended & Restated Common Terms Agreement


  (e)

Cash Flow applied or committed to be applied to Development Expenditures that are not committed under the Base Case Forecast or otherwise committed to fund development of Project Costs (including (i) Pre-Completion Revenues transferred from the Phase 1 Pre-Completion Revenues Account to the Construction Account or the Contingency Reserve Account in accordance with Section 4.5(b)(ii)(C) (Deposits and Withdrawals – Phase 1 Pre-Completion Revenues Account) of the Common Security and Account Agreement, (ii) Pre-Completion Revenues transferred from the Phase 2 Pre-Completion Revenues Account to the Construction Account or the Contingency Reserve Account in accordance with Section 4.5(c)(ii)(C) (Deposits and Withdrawals – Phase 2 Pre-Completion Revenues Account) of the Common Security and Account Agreement and (iii) on and following the Project Phase 1 Completion Date, proceeds on deposit in the Revenue Account at the eighth or eleventh level of priority in the waterfall in Section 4.7 (Cash Waterfall) of the Common Security and Account Agreement to the extent permitted by Section 4.7(a)(viii) (Cash Waterfall) or 4.7(a)(xi) (Cash Waterfall) of the Common Security and Account Agreement, as applicable, and, in each case, applied towards such Development Expenditures);

 

  (f)

any Drawstop Equity Contributions, to the extent not reimbursed pursuant to Section 11.2(c) (Certain Restricted Payments); and

 

  (g)

following the Project Phase 2 Completion Date, Cash Flows applied towards other capital expenditures in respect of the Project Facilities; provided that such Cash Flows following the Project Phase 2 Completion Date would qualify to be distributed as Restricted Payments based on meeting the conditions set forth in Section 11.1 (Conditions to Restricted Payments) of the Common Terms Agreement or are otherwise eligible to be used for Required Capital Expenditures.

Equity Interests” means any and all shares, interests, participations or other equivalents (however designated) of capital stock of a corporation, any and all equivalent ownership interests in a Person (other than a corporation), including partnership interests and membership interests, and any and all warrants, rights or options to purchase or other arrangements or rights to acquire any of the foregoing.

ERISA” means the Employee Retirement Income Security Act of 1974.

ERISA Affiliate” means any Person, or trade or business that is a member of any group of organizations: (a) described in Section 414(b), (c), (m) or (o) of the Code of which the Borrower is a member and (b) solely for purposes of potential liability under Section 302(b) of ERISA and Section 412(b) of the Code and the lien created under Section 303(k) of ERISA and Section 430(k) of the Code, described in Section 414(m) or (o) of the Code of which an Obligor is a member.

 

-214-

Plaquemines – Amended & Restated Common Terms Agreement


ERISA Event” means:

 

  (a)

any “reportable event,” as defined in Section 4043 of ERISA or the regulations issued thereunder with respect to a Plan, other than events for which the 30-day notice period has been waived by current regulation under PBGC Regulation Subsections .27, .28, .29 or .31;

 

  (b)

the failure with respect to any Plan to meet the minimum funding requirements of Section 412 or 430 of the Code or Section 302 or 303 of ERISA, whether or not waived;

 

  (c)

the filing pursuant to Section 412(c) of the Code or Section 303 of ERISA of an application for a waiver of the minimum funding standard with respect to any Plan;

 

  (d)

the incurrence by an Obligor or any of its ERISA Affiliates of any liability under Title IV of ERISA with respect to the termination of any Plan;

 

  (e)

the filing of notice of intent to terminate a Plan or the treatment of a Plan amendment as a termination under Section 4041 of ERISA;

 

  (f)

the institution of proceedings to terminate a Plan by PBGC or to appoint a trustee to administer any Plan;

 

  (g)

the withdrawal by an Obligor or any of its ERISA Affiliates from a multiple employer plan (within the meaning of Section 4064 of ERISA) during a plan year in which it was a “substantial employer,” as such term is defined under Section 4064 of ERISA, upon the termination of a Multiemployer Plan or the cessation of operations under a Plan pursuant to Section 4062(e) of ERISA;

 

  (h)

the incurrence by an Obligor or any of its ERISA Affiliates of any liability with respect to the withdrawal or partial withdrawal from any Multiemployer Plan;

 

  (i)

the attainment of any Plan of “at risk” status within the meaning of Section 430 of the Code or Section 303 of ERISA;

 

  (j)

the receipt by an Obligor or any ERISA Affiliate of any notice, or the receipt by any Multiemployer Plan from an Obligor or any ERISA Affiliate of any notice, concerning the imposition of Withdrawal Liability or a determination that a Multiemployer Plan is, or is expected to be, insolvent or in critical, endangered or seriously endangered status, within the meaning of the Code or Title IV of ERISA;

 

  (k)

the failure of an Obligor or any ERISA Affiliate to pay when due any amount that has become liable to the PBGC, any Plan or trust established thereunder pursuant to Title IV of ERISA or the Code;

 

-215-

Plaquemines – Amended & Restated Common Terms Agreement


  (l)

the adoption of an amendment to a Plan requiring the provision of security to such Plan pursuant to Section 436(f) of the Code;

 

  (m)

an Obligor engages in a “prohibited transaction” within the meaning of Section 4975 of the Code or Section 406 of ERISA that is not otherwise exempt by statute, regulation or administrative pronouncement; or

 

  (n)

the imposition of a lien under ERISA or the Code with respect to any Plan or Multiemployer Plan.

EU Bail-In Legislation Schedule” means the EU Bail-In Legislation Schedule published by the Loan Market Association (or any successor Person), as in effect from time to time.

Event of Default” means a Loan Facility Event of Default, an Indenture Event of Default or any comparable Obligor event of default under any other Senior Debt Instrument entered into after the date of the Common Security and Account Agreement.

Event of Loss” means any event that causes any Project Facilities, or any portion thereof to be damaged, destroyed or rendered unfit for normal use for any reason whatsoever and, in each case, shall include an Event of Taking.

Event of Taking” means any taking, seizure, confiscation, requisition, exercise of rights of eminent domain, public improvement, inverse condemnation, condemnation or similar action of or proceeding by any Governmental Authority relating to all or any part of the Project Facilities, the Development, any Equity Interests in the Obligors or any other part of the Security Interests.

Excelerate” means Excelerate Gas Marketing, Limited Partnership.

Excess Capacity LNG SPAs” means the Phase 1 Excess Capacity LNG SPA and the Phase 2 Excess Capacity LNG SPA.

Excess Capacity Quantity” means the positive difference between (A) the quantity of LNG produced by the LNG Facility and (B) 20.0 MTPA of LNG.

Excess Equity Proceeds Account” means the account described in Section 4.3(a)(xvi) (Accounts) of the Common Security and Account Agreement.

Excluded Accounts” means Excluded Unsecured Accounts and any escrow account established under each Material Construction Contract.

Excluded Assets” has the meaning given in Section 3.2(f) (Security Interests to be Granted by the Obligors Excluded Assets) of the Common Security and Account Agreement.

 

-216-

Plaquemines – Amended & Restated Common Terms Agreement


Excluded Swap Obligation” means, with respect to any Obligor, any Swap Obligation if, and to the extent that, all or a portion of the guarantee of such Obligor of, or the grant by such Obligor of a security interest to secure, such Swap Obligation (or any guarantee thereof) is or becomes illegal under the Commodity Exchange Act or any rule, regulation or order of the Commodity Futures Trading Commission (or the application or official interpretation of any thereof) by virtue of such Obligor’s failure for any reason to constitute an “eligible contract participant” as defined in the Commodity Exchange Act and the regulations thereunder at the time the guarantee of such Obligor or the grant of such security interest becomes effective with respect to such Swap Obligation. If a Swap Obligation arises under a master agreement governing more than one swap, such exclusion shall apply only to the portion of such Swap Obligation that is attributable to swaps for which such guarantee or security interest is or becomes illegal.

Excluded Tax” means any of the following Taxes imposed on or with respect to a Finance Party or required to be withheld or deducted from a payment to a Finance Party:

 

  (a)

Taxes imposed on or measured by net income (however denominated), franchise Taxes, and branch profits Taxes, in each case, (i) imposed as a result of such Finance Party being organized under the laws of, or having its principal office or, in the case of any Facility Lender, its applicable lending office located in, the jurisdiction imposing such Tax (or any political subdivision thereof) or (ii) that are Other Connection Taxes;

 

  (b)

in the case of a Facility Lender, US federal withholding Tax imposed on amounts payable to or for the account of such Facility Lender pursuant to a law in effect at the time such Facility Lender acquires an interest in a Loan or Facility Debt Commitment or designates a new lending office (other than pursuant to an assignment or new lending office designation request by the Borrower), except to the extent that such Facility Lender (or its assignor, if any) was entitled, at the time of such designation of a new lending office (or assignment), to receive additional amounts from the Borrower with respect to such withholding Tax pursuant to the Facility Agreement provisions described in Section 21.1 (Withholding Tax Gross-Up) of the Common Terms Agreement;

 

  (c)

Taxes attributable to a Facility Lender’s failure to comply with the provisions described in Section 21.5 (Status of Facility Lenders and Facility Agents) of the Common Terms Agreement; or

 

  (d)

withholding Taxes imposed under FATCA.

 

-217-

Plaquemines – Amended & Restated Common Terms Agreement


Excluded Unsecured Accounts” has the meaning given in Section 3.2(f)(iv) (Security Interests to be Granted by the Obligors Excluded Assets) of the Common Security and Account Agreement.

Existing Facility Lender” has the meaning given in Section 19.6 (Transfers by a Facility Lender) of the Common Terms Agreement.

Expansion” has the meaning given in Section 7.2 (Expansion Contracts) of the Common Terms Agreement.

Export Authorization” means a long-term, multi-contract authorization issued by the DOE to export LNG from the LNG Facility, including the FTA Authorization and the Non-FTA Authorization.

Export Authorization Remediation” has the meaning given in Section 8.2(a)(ii)(A) (LNG SPA Mandatory Prepayment) of the Common Terms Agreement.

Exxon” means ExxonMobil LNG Asia Pacific (EMLAP), a registered business name of ExxonMobil Asia Pacific Pte. Ltd.

Facility Agent” means the facility agent under any Facility Agreement.

Facility Agreements” means the Credit Facility Agreement and any individual loan facility agreements (not including any Indenture or facility agreement for a “term loan B” financing that the Borrower has elected to treat as an Indenture) evidencing permitted Replacement Debt, and/or Working Capital Debt (and for which the Facility Agents have acceded to the Common Terms Agreement and to the Common Security and Account Agreement), in each case as required thereby, and “Facility Agreement” shall have a corresponding meaning.

Facility Debt Commitment” means the aggregate principal amount of Loans and letters of credit any Facility Lender is committed to disburse to or issue on behalf of the Borrower under any Facility Agreement.

Facility Debt Obligations” means the Senior Debt Obligations arising under the Facility Agreements.

Facility Lenders” means the Credit Facility Lender Parties and the lenders and issuing banks under any other Facility Agreements entered into after the Initial Closing Date, and “Facility Lender” shall have a corresponding meaning.

Fair Labor Standards Act” means the Fair Labor Standards Act of 1938.

 

-218-

Plaquemines – Amended & Restated Common Terms Agreement


FATCA” means Sections 1471 through 1474 of the Code, as of the Initial Closing Date (or any amended or successor version that is substantively comparable and not materially more onerous to comply with), any current or future regulations or official interpretations thereof, any agreements entered into pursuant to Section 1471(b)(1) of the Code, any intergovernmental agreement, treaty or convention entered into in connection with the implementation of such Sections of the Code and any fiscal or regulatory legislation, rules or official practices adopted pursuant to such intergovernmental agreement and implementing any of the foregoing.

Federal Reserve Bank” means each of the 12 Reserve Banks under the United States Federal Reserve System, or any successor thereto.

Federal Reserve Board” means the Board of Governors of the United States Federal Reserve System, or any successor thereto.

Fee Letters” means the Intercreditor Agency Fee Letter, the Account Bank Fee Letter, the Collateral Agency Fee Letter, the Credit Facility Agency Fee Letter, the Documentation Bank Fee Letters and any other similar fee letter, fee agreement or other fee arrangement between an Obligor and a Facility Agent, or between an Obligor and any of the Account Bank, Intercreditor Agent, Collateral Agent, Credit Facility Agent or other Facility Agent or Facility Lender that may be entered into from time to time after the date of the Common Security and Account Agreement.

FERC” means the US Federal Energy Regulatory Commission.

FERC Order” means the order, 168 FERC ¶ 61,204 (2019), issued by the FERC in Docket Nos. CP17-66-000 and CP17-67-000 on September 30, 2019 authorizing, inter alia, the siting, construction and operation of the LNG Facility and the Gator Express Pipeline.

Final Maturity Date” means, with respect to each of the Facility Agreements, the date on which all Senior Debt under such Facility Agreement comes due, whether upon acceleration or otherwise.

Finance Documents” means, together, each of the following documents:

 

  (a)

the Common Terms Agreement;

 

  (b)

the Common Security and Account Agreement;

 

  (c)

the individual Facility Agreements;

 

  (d)

any Indenture;

 

  (e)

the Security Documents;

 

  (f)

the Direct Agreements;

 

  (g)

the Senior Notes;

 

-219-

Plaquemines – Amended & Restated Common Terms Agreement


  (h)

the Intercreditor Agreement;

 

  (i)

the Fee Letters and any fee letters with parties providing financing (other than any Equity Funding);

 

  (j)

any Permitted Senior Debt Hedging Instrument; and

 

  (k)

any other document the Intercreditor Agent (acting on the instructions of the Requisite Intercreditor Parties) designates, with the consent of the Borrower (such consent not to be unreasonably withheld), a Finance Document;

provided that when used with respect to the Facility Lenders, such term shall not include any Indenture or Senior Notes and when used with respect to the Senior Notes, such term shall not include the Common Terms Agreement, Facility Agreement or any other Finance Document to which the Indenture Trustee is not a party or under which security is not intended to be granted for the benefit of the Senior Notes.

Finance Party” means each Facility Lender, the Intercreditor Agent, the Collateral Agent, each Senior Creditor Group Representative (in its own right and in its capacity as agent), each Hedging Bank and the Account Bank.

First of Month Index” means a price which represents the most commonly traded fixed price at a major trading point and as published by Inside FERC Gas Market Report (“IFERC” or any successor publication widely used to establish index pricing in the US natural gas trading market).

First Repayment Date”, with respect to the Credit Facility Agreement, has the meaning given in the Credit Facility Agreement.

First Upsize Repayment Date”, with respect to the Credit Facility Agreement, has the meaning given in the Credit Facility Agreement.

Fitch” means Fitch Ratings Ltd. or any successor thereto.

Fixed Facility Charge” has the meaning given in the applicable LNG SPA.

Fixed-Floating Futures Swap” means a contract which entitles the buyer of the contract to pay a fixed price for natural gas and the seller to pay a floating price equal to the final settlement price of the Futures Contract settlement prices. The Fixed-Floating Futures Swap shall be settled financially, via exchange of cash payment at the expiration of the underlying Futures Contract, rather than physically.

 

-220-

Plaquemines – Amended & Restated Common Terms Agreement


Fixed Projected DSCR” means, for each applicable measurement period, the ratio of:

 

  (a)

the Cash Flow Available for Debt Service projected for such period, calculated solely to reflect (i) the Fixed Facility Charge under each of the Qualifying LNG SPAs then in effect, (ii) expected interest and investment earnings paid to the Obligors during such period, (iii) amounts expected to be paid to the Obligors during such period as Business Interruption Insurance Proceeds and (iv) the fixed expenses that could reasonably be expected to be incurred by the Obligors if the Material Project Counterparties were not lifting any cargoes under the Qualifying LNG SPAs; to

 

  (b)

Senior Debt Obligations projected to be paid in such period (taking into account Permitted Hedging Instruments) (other than (i) pursuant to voluntary prepayments or mandatory prepayments, (ii) Senior Debt due at maturity, (iii) Working Capital Debt, (iv) Hedging Termination Amounts, and (v) for any period prior to the Project Phase 2 Completion Date, (A) Senior Debt Obligations with respect to the Term Loan Commitments other than Debt Service and (B) pursuant to Permitted Hedging Instrument with respect to the Incremental Senior Debt).

Flood Certificate” has the meaning given in Section 4.1(t)(i) (Conditions to Initial Closing Date and Initial Advance – Flood Insurance) of the Common Terms Agreement.

Flood Program” has the meaning given in Section 4.1(t)(i)(C) (Conditions to Initial Closing Date and Initial Advance – Flood Insurance) of the Common Terms Agreement.

FOB” means Free on Board as defined in Incoterms 2010.

FTA Authorization” means the Order Granting Long-Term, Multi-Contract Authorization to Export LNG to Free Trade Agreement Nations issued by DOE/FE in FE Docket No. 16-28-LNG in its Order No. 3866 on July 21, 2016, as amended to extend the term in DOE/FE Order No. 3866-A issued on October 21, 2020, and amended to increase the authorized export volumes in DOE/FE Order No. 3866-B issued on June 13, 2022.

Fund” means any Person that is (or will be) engaged in making, purchasing, holding or otherwise investing in commercial loans and similar extensions of credit.

Funding Losses” under a Facility Agreement means those losses, expenses or liabilities in respect of Loans incurred by the respective Facility Lenders under such Facility Agreement that the Borrower is required to compensate such Facility Lenders in respect of thereunder.

 

-221-

Plaquemines – Amended & Restated Common Terms Agreement


Futures Contract” means a contract which entitles the buyer of the contract to claim physical delivery of natural gas from the seller at a specified contract delivery point at a specified date in the future and entitles the seller to deliver the physical commodity to the buyer under the same conditions. The price between the buyer and the seller shall be transacted at the price of final settlement on a monthly basis.

GAAP” means generally accepted accounting principles in the jurisdiction in which the relevant party’s financial statements are prepared or International Accounting Standards/International Financial Reporting Standards, as in effect from time to time.

Gas” means any hydrocarbon or mixture of hydrocarbons consisting essentially of methane and other paraffinic hydrocarbons and non-combustible gases in a gaseous state.

Gas Hedge Provider” means any party (other than the Obligors or their Affiliates) that is a party to a Gas Hedging Instrument that is secured pursuant to the Security Documents.

Gas Hedging Instruments” means Gas swaps, options contracts, futures contracts, options on futures contracts, caps, floors, collars or any other similar arrangements entered into by any Obligor related to movements in Gas prices.

Gas Sourcing Plan” means the plan set forth in Schedule K (Gas Sourcing Plan) of the Common Terms Agreement, as updated semi-annually by delivery by the Borrower of an updated plan, and related attachments and exhibits, by the Borrower to the Intercreditor Agent.

Gas Transportation Agreements” means:

 

  (a)

Amended and Restated Precedent Agreement (240,000 Dth/d MDQ), dated as of December 21, 2020, by and between the Borrower and Texas Eastern Transmission, LP;

 

  (b)

Amended and Restated Precedent Agreement (1,260,000 Dth/d MDQ), dated as of December 21, 2020, by and between the Borrower and Texas Eastern Transmission, LP, as superseded by the service agreement described therein, and as amended by the Waiver Letter, dated as of December 8, 2021;

 

  (c)

Second Amended and Restated Precedent Agreement, dated as of December 9, 2021, by and between the Borrower and Tennessee Gas Pipeline Company, L.L.C.;

 

-222-

Plaquemines – Amended & Restated Common Terms Agreement


  (d)

Amended and Restated Precedent Agreement for Firm Natural Gas Transportation Service re: East Lateral Xpress Project, dated as of December 17, 2021, by and between the Borrower and Columbia Gulf Transmission, LLC as amended by the First Amendment thereto dated as of September 27, 2022; and

 

  (e)

Amended and Restated Precedent Agreement—Anchor Shipper for Firm Transportation Service, dated as of September 30, 2019, by and between the Borrower and the Guarantor.

Gator Express Pipeline” means the two lateral pipelines that are collectively approximately 26 miles long (and related facilities) connecting the LNG Facility to the existing interstate and intrastate natural gas pipeline system to receive feed gas for liquefaction and the power plant in each case, as described in the application filed by the Guarantor, pursuant to Section 7(c) of the Natural Gas Act, and its subsequent filings, in FERC Docket No. CP17-67.

Government Rule” means any statute, law, regulation, ordinance, rule, judgment, order, decree, directive, requirement of, or other governmental restriction or any similar binding form of decision of or determination by, or any interpretation or administration of any of the foregoing by, any Governmental Authority, including all common law, which is applicable to any Person, whether now or hereafter in effect.

Governmental Authorities” means all supra-national, federal, state and local authorities or bodies including in each case any and all agencies, branches, departments and administrative and other subdivisions thereof, and all officials, agents and representatives of each of the foregoing, and “Governmental Authority” shall have a corresponding meaning.

Guarantor” means Venture Global Gator Express, LLC, a limited liability company organized under the laws of the State of Delaware, which is a direct wholly owned Subsidiary of the Pledgor, and any Subsidiary of the Borrower that accedes to the Common Security and Account Agreement from time to time as permitted under the Finance Documents then in effect as a Guarantor for the benefit of all Senior Creditors, pursuant to Section 11.15 (Additional Guarantors) of the Common Security and Account Agreement.

Guarantor Interests” means the Equity Interests in the Guarantor.

Hague Securities Convention” means the Convention on the Law Applicable to Certain Rights in Respect of Securities Held with an Intermediary (concluded July 5, 2006), which became effective in the United States on April 1, 2017.

 

-223-

Plaquemines – Amended & Restated Common Terms Agreement


Hazardous Materials” means:

 

  (a)

petroleum or petroleum byproducts, flammable materials, explosives, radioactive materials, friable asbestos, urea formaldehyde foam insulation and polychlorinated biphenyls;

 

  (b)

any chemicals, other materials, substances or wastes that are now or hereafter become defined as or included in the definition of “hazardous substances,” “hazardous wastes,” “hazardous materials,” “extremely hazardous wastes,” “restricted hazardous wastes,” “toxic substances,” “toxic pollutants,” “contaminants,” “pollutants” or words of similar import under any Environmental Law; and

 

  (c)

any other chemical, material, substance or waste that is now or hereafter regulated under or with respect to which liability may be imposed under Environmental Laws.

Hedging Bank” means a Person that is a counterparty to a Permitted Hedging Instrument with the Borrower and that has entered into or that accedes to the Common Security and Account Agreement, and is as of the date of entry into or assignment or novation of any Permitted Hedging Instrument (or, with respect to any Anticipatory Hedge or assignment or novation thereof, as of the Initial Closing Date or as of the date of assignment or novation), any of the following: (a) any Senior Creditor, lead arranger or agent, as of the date of the Original Common Terms Agreement, the Upsize Closing Date or as of the date of entry into or assignment or novation of any Permitted Hedging Instrument, or (b) any Affiliate of any Person listed in the foregoing clause (a) of this definition.

Hedging Excess Amount” has the meaning given in Section 12.22(c) (Hedging Arrangements) of the Common Terms Agreement.

Hedging Instruments” means:

 

  (a)

Interest Rate Hedging Instruments;

 

  (b)

Gas Hedging Instruments; and

 

  (c)

such other derivative transactions of a similar nature that any Obligor enters into to hedge risks of any commercial nature.

Hedging Termination Amount” means any Permitted Hedging Liability due as a result of the termination of a Permitted Hedging Instrument and/or the termination of any transaction entered into thereunder.

Historical DSCR” means, for each applicable measurement period, the ratio of (a) Cash Flow Available for Debt Service for such measurement period to (b) Debt Service for such measurement period (other than (i) pursuant to voluntary prepayments or mandatory prepayments, (ii) Senior Debt due at maturity, (iii)

 

-224-

Plaquemines – Amended & Restated Common Terms Agreement


Working Capital Debt, (iv) Hedging Termination Amounts and (v) for any period prior to the Project Phase 2 Completion Date, (A) Senior Debt Obligations with respect to the Term Loan Commitments other than Debt Service and (B) pursuant to Permitted Hedging Instrument with respect to the Incremental Senior Debt); provided, that in respect of any measurement period occurring prior to the first full year after the Project Phase 1 Completion Date, each of clauses (a) and (b) shall be calculated on an annualized basis for such measurement periods.

Holder” of a Senior Debt Obligation shall be determined by reference to the provisions of the relevant Senior Debt Instrument or Permitted Senior Debt Hedging Instrument, as applicable, setting forth who shall be deemed to be lenders, creditors, holders or owners of the debt obligation governed thereby.

Illegality Event” has the meaning given in Section 19.5(b) (Mitigation Obligations; Replacement of Lenders) of the Common Terms Agreement.

Impairment” means, with respect to any Permit:

 

  (a)

the rescission, revocation, staying, withdrawal, early termination, cancellation, repeal or invalidity thereof or otherwise ceasing to be in full force and effect;

 

  (b)

the suspension or injunction thereof; or

 

  (c)

the inability to satisfy in a timely manner its stated conditions to effectiveness.

Impair” and “Impaired” shall have a corresponding meaning.

Incremental Senior Creditor” means each Senior Creditor under the Credit Facility Agreement that becomes a Senior Creditor as of or following the Upsize Closing Date.

Incremental Senior Debt” means the incremental Senior Debt Obligations incurred under the Credit Facility Agreement as of the Upsize Closing Date (for the avoidance of doubt, as of the Upsize Closing Date, the principal amount of which is $5,488,883,831.90).

Incremental Senior Debt Commitment” means the Senior Debt Commitments of an Upsize Senior Creditor with respect to the Incremental Senior Debt.

Indebtedness” of any Person, at any date, means:

 

  (a)

all obligations to repay borrowed money;

 

-225-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

all obligations to pay money evidenced by bonds, debentures, notes, banker’s acceptances, loan agreements or other similar instruments;

 

  (c)

all obligations to pay the deferred purchase price of property or services (excluding current accounts payable incurred in the ordinary course of business);

 

  (d)

all capital lease obligations of such Person;

 

  (e)

all obligations, contingent or otherwise, issued for the account of such Person, in respect of letters of credit, bank guarantees, surety bonds, letters of guarantee and similar instruments;

 

  (f)

all obligations of such Person under any Hedging Instruments (including any Hedging Termination Amounts);

 

  (g)

all guarantees by such Person of Indebtedness of others;

 

  (h)

any obligations of such Person to purchase or repurchase securities or other property which arises out of or in connection with the sale of the same or substantially similar securities or property;

 

  (i)

all obligations under conditional sale or other title retention agreements related to property acquired by such Person (even though the rights and remedies of the seller or lender under such agreement in the event of default are limited to repossession or sale of property or are otherwise limited in recourse);

 

  (j)

all Indebtedness of others secured by (or for which the holder of such Indebtedness has an existing right, contingent or otherwise, to be secured by) any Lien on property owned or acquired by such Person, whether or not the Indebtedness secured thereby has been assumed;

 

  (k)

all obligations to purchase, redeem, retire, defease or otherwise make any payment in respect of any Equity Interests of such Person or any other Person or any warrants, rights or options to acquire such equity interests, which in the case of redeemable preferred interests, being valued at the greater of its voluntary or involuntary liquidation preference plus accrued and unpaid dividends; and

 

  (l)

all Indebtedness of any other entity (including any partnership in which such Person is a general partner) to the extent such Person is liable therefor as a result of such Person’s ownership interest in or other relationship with such entity, except to the extent the terms of such Indebtedness provide that such Person is not liable therefor.

 

-226-

Plaquemines – Amended & Restated Common Terms Agreement


Indemnified Taxes” means (a) Taxes, other than Excluded Taxes, imposed on or with respect to any payment made by or on account of any obligation of an Obligor under or in connection with any Finance Document (other than any Indenture or Senior Notes) and (b) to the extent not otherwise described in clause (a) of this definition, Other Taxes.

Indenture” means any indenture to be entered into between the Borrower and the Indenture Trustee pursuant to which one or more series of Senior Notes will be issued, or, at the Borrower’s option, a facility agreement for a “term loan B” financing, pursuant to which Senior Debt will be incurred. No reference in any Finance Document to an Indenture or the Senior Notes or a “term loan B” shall mean or imply that entry into an Indenture or issuance of the Senior Notes or entry into a “term loan B” is required. For the avoidance of doubt, if at any time Senior Notes have not been issued or are not outstanding and there is no “term loan B”, any reference to satisfaction of the requirements of any Indenture or Senior Notes or the “term loan B” (and any reference to an Indenture Trustee) shall be ignored.

Indenture Declared Default” means an Indenture Event of Default which is declared by the Indenture Trustee (acting on behalf of the Senior Noteholders in accordance with such Indenture) to be an event of default under an Indenture or is otherwise deemed to have been declared to be an event of default in accordance with the terms of the Indenture.

Indenture Event of Default” means any of the events of default set out in an Indenture and defined as “Indenture Events of Default.”

Indenture Projected Fixed DSCR” has the meaning given in the applicable Indenture.

Indenture Trustee” means any trustee appointed in the role of indenture trustee under any Indenture or, with respect to a “term loan B” financing that the Borrower has elected to be treated as an Indenture, any administrative or other facility agent.

Independent Accountants” means any independent firm of accountants of recognized standing in the relevant jurisdiction.

Independent Engineer” means Lummus Consultants International LLC or any replacement independent engineering consulting firm selected in accordance with Section 13.2 (Replacement and Fees) of the Common Terms Agreement.

Index Swap” means a contract which entitles the buyer of the contract to pay one index price (e.g. First of Month Index) and entitles the seller to pay a different index price (e.g. the daily average). The index swap is settled financially via exchange of cash payment at the expiration of the underlying Futures Contract.

 

-227-

Plaquemines – Amended & Restated Common Terms Agreement


Individual Senior Noteholder Secured Accounts” has the meaning given in Section 3.2(c) (Security Interests to be Granted by the Obligors – Security Interests – Individual Senior Noteholder Secured Accounts) of the Common Security and Account Agreement.

Industry Standards” means the technical standards promulgated by the American Petroleum Institute, the American Gas Association, the American Society of Mechanical Engineers, the ASTM (formerly the American Society for Testing and Materials), or the National Fire Protection Association (NFPA).

Initial Advance” means the first Advance of the Term Loans on the Initial Closing Date following the satisfaction or waiver of the conditions precedent in Sections 4.1 (Conditions to Initial Closing Date and Initial Advance) and 4.3 (Conditions to Each Term Loan Advance) of the Common Terms Agreement in accordance with Section 4.5 (Satisfaction of Conditions) of the Common Terms Agreement.

Initial Closing” means the satisfaction or waiver of all the conditions precedent set forth in Section 4.1 (Conditions to Initial Closing Date and Initial Advance) and Section 4.3 (Conditions to Each Term Loan Advance) of the Common Terms Agreement, with respect to the Initial Senior Debt.

Initial Closing Conditions Certificate” has the meaning given in Section 4.5(a)(i) (Satisfaction of Conditions) of the Common Terms Agreement.

Initial Closing Date” means the date on which the conditions precedent set forth in Section 4.1 (Conditions to Initial Closing Date and Initial Advance) and Section 4.3 (Conditions to Each Term Loan Advance) of the Common Terms Agreement have been satisfied or waived. For the avoidance of doubt, the Initial Closing Date is May 25, 2022.

Initial Closing Notice” has the meaning given in Section 4.5(a)(i) (Satisfaction of Conditions) of the Common Terms Agreement.

Initial Commitment Letter” means that certain Commitment Letter, dated as of May 14, 2022, by and among, the Obligors and the Banks (as defined therein) party thereto.

Initial LNG Buyers” means the Phase 1 Initial LNG Buyers and the Phase 2 Initial LNG Buyers.

Initial LNG SPA Guarantees” means the Phase 1 Initial LNG SPA Guarantees and the Phase 2 Initial LNG SPA Guarantees.

Initial LNG SPAs” means the Phase 1 Initial LNG SPAs and the Phase 2 Initial LNG SPAs.

 

-228-

Plaquemines – Amended & Restated Common Terms Agreement


Initial Permitted Senior Debt Hedging Instrument” means each Permitted Senior Debt Hedging Instrument identified as such in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement as of the Upsize Closing Date.

Initial Senior Creditor” means each Senior Creditor under the Original Credit Facility Agreement or an Initial Permitted Senior Debt Hedging Instrument.

Initial Senior Creditor Group Representative” means each Hedging Bank acting in the capacity as a Senior Creditor Group Representative prior to the Upsize Closing Date and which is identified as such on Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement.

Initial Senior Debt” means the Senior Debt Obligations owing under the Credit Facility Agreement as of the Initial Closing Date.

Initiating Percentage” means Senior Creditor Group Representatives representing the following percentages of the principal amount of Senior Debt Obligations outstanding during the following periods (or, if no Senior Debt is outstanding, commitments in respect thereof):

 

  (a)

with respect to any Payment Default:

 

  (i)

at least 66.7% prior to 30 days following the occurrence of a Payment Default or the declaration thereof, as the case may be;

 

  (ii)

greater than 50% on or after 30 days and prior to 120 days following the occurrence of a Payment Default or the declaration thereof, as the case may be; and

 

  (iii)

the lesser of $200 million or 5% of the outstanding Senior Debt held by any individual Senior Creditor Group, on or after 120 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof, as the case may be; and

 

  (b)

with respect to any other Event of Default:

 

  (i)

at least 66.7% on or prior to 30 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof, as the case may be;

 

-229-

Plaquemines – Amended & Restated Common Terms Agreement


  (ii)

greater than 50% on or after 30 days and prior to 180 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof, as the case may be; and

 

  (iii)

the lesser of $200 million or 5% of the outstanding Senior Debt held by any individual Senior Creditor Group, on or after 180 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof, as the case may be.

Insurance” means (a) all insurance policies covering any or all of the Collateral (regardless of whether the Collateral Agent is the loss payee thereof) and (b) any key man life insurance policies.

Insurance Advisor” means Moore-McNeil, LLC or any independent replacement insurance consulting firm to be selected in accordance with Section 13.2 (Replacement and Fees) of the Common Terms Agreement.

Insurance/Condemnation Proceeds Account” is the account described in Section 4.3(a)(x) (Accounts) of the Common Security and Account Agreement.

Insurance Proceeds” means all proceeds of any insurance policies required pursuant to the Schedule of Minimum Insurance or otherwise obtained with respect to the Development that are paid or payable to or for the account of the Obligors as loss payee (other than Business Interruption Insurance Proceeds and proceeds of insurance policies relating to third party liability).

Intellectual Property” means the collective reference to all rights, priorities and privileges relating to intellectual property, whether arising under the United States, multinational or foreign laws or otherwise, including Copyrights, Copyright Licenses, Patents, Patent Licenses, Trademarks, Trademark Licenses, Trade Secrets, and Trade Secret Licenses, and all rights to sue or otherwise recover for any past, present and future infringement, dilution, misappropriation, or other violation or impairment thereof, including the right to receive all proceeds therefrom, including license fees, royalties, income, payments, claims, damages and proceeds of suit, now or hereafter due and/or payable with respect thereto.

Intercreditor Agency Fee Letter” means the fee letter dated as of the Initial Closing Date entered into between the Borrower, the Guarantor and the Intercreditor Agent in respect of the fees payable to the Intercreditor Agent in respect of its services to be performed as more fully described in the Common Security and Account Agreement and the other Security Documents.

 

-230-

Plaquemines – Amended & Restated Common Terms Agreement


Intercreditor Agent” means the intercreditor agent appointed pursuant to the Intercreditor Agreement.

Intercreditor Agreement” means the Amended and Restated Intercreditor Agreement, dated as of the Upsize Closing Date, among the Intercreditor Agent, the Collateral Agent and the Facility Agents and Hedging Banks party thereto from time to time, setting forth the appointment of the Intercreditor Agent and setting forth voting and certain intercreditor arrangements among all Facility Lenders and Hedging Banks.

Interest Rate Hedging Instrument” means interest rate swaps, option contracts, futures contracts, options on futures contracts, caps, floors, collars or any other similar arrangements entered into by the Borrower related to interest rates.

International LNG Terminal Standards” means, to the extent not inconsistent with the express requirements of the Common Terms Agreement, the international standards and practices applicable to the design, construction, equipment, operation or maintenance of LNG receiving, exporting, liquefaction and regasification terminals, established by the following (such standards to apply in the following order of priority): (a) a Governmental Authority having jurisdiction over any Obligor, (b) the Society of International Gas Tanker and Terminal Operators (“SIGTTO”) (or any successor body of the same) and (c) any other internationally recognized non-governmental agency or organization with whose standards and practices it is customary for reasonable and prudent operators of LNG receiving, exporting, liquefaction and regasification terminals to comply. In the event of a conflict between any of the priorities noted above, the priority with the alphabetical priority noted above shall prevail.

International LNG Vessel Standards” means, to the extent not inconsistent with the express requirements of the Common Terms Agreement, the international standards and practices applicable to the ownership, design, equipment, operation or maintenance of LNG vessels established by: (a) the International Maritime Organization, (b) the Oil Companies International Marine Forum, (c) SIGTTO (or any successor body of the same), (d) the International Navigation Association, (e) the International Association of Classification Societies, and (f) any other internationally recognized agency or nongovernmental organization with whose standards and practices it is customary for reasonable and prudent operators of LNG vessels to comply. In the event of a conflict between any of the priorities noted above, the priority with the alphabetical priority noted above shall prevail.

Investment Company Act” means the United States Investment Company Act of 1940.

Investment Grade” means two long-term unsecured credit ratings that are equal to or better than (a) Baa3 by Moody’s, (b) BBB- by S&P, (c) BBB- by Fitch, or (d) any comparable credit ratings by any other nationally recognized statistical rating organizations.

 

-231-

Plaquemines – Amended & Restated Common Terms Agreement


Investment Grade LNG Buyer” means an LNG Buyer that (a) is Investment Grade, (b) has its obligations guaranteed by an Investment Grade entity or (c) for the purposes of LNG SPAs in Section 8.1(a) (LNG SPA Maintenance), Section 8.2(a)(i) (LNG SPA Mandatory Prepayment) or Section 11.1 (Conditions to Restricted Payments) of the Common Terms Agreement, has all of its obligations under the applicable LNG SPA supported by a letter of credit issued by an Acceptable Bank.

Issuance Request Form” means a Disbursement Request for issuance of letter(s) of credit, substantially in the form set forth in Schedule B-3 (Issuance Request Form (Letters of Credit)) to the Common Terms Agreement (or equivalent under another Senior Debt Instrument), given by the Borrower in accordance with the terms of the applicable Facility Agreement.

Issuing Banks” has the meaning given to it in Exhibit A (Definitions) to the Credit Facility Agreement.

Judgment Currency” has the meaning given in Section 12.3 (Judgment Currency) of the Common Security and Account Agreement.

Knowledge” means, with respect to any of the Obligors, the actual or constructive knowledge of any Person holding any of the positions (or successor position to any such position) set forth in Schedule T (Knowledge Parties) to the Common Terms Agreement; provided that each such Person shall be deemed to have knowledge of all events, conditions and circumstances described in any notice delivered to the Borrower pursuant to the terms of the Common Terms Agreement or any other Finance Document. “Knowingly” shall have a corresponding meaning.

LC Costs” means (a) fees, expenses and interest associated with Working Capital Debt and (b) any reimbursement by an Obligor of amounts paid under a letter of credit that is Working Capital Debt for expenditures that if paid by such Obligor directly would have constituted Operation and Maintenance Expenses.

LC Reimbursement Payment” has the meaning assigned to such term in the Credit Facility Agreement.

Leases” means:

 

  (a)

Ground Lease Agreement (Parcel 2), dated as of July 19, 2021, between the Borrower and The Plaquemines Port Harbor and Terminal District; and

 

  (b)

Ground Lease Agreement (Laydown Area), dated as of July 19, 2021, between the Borrower and The Plaquemines Port Harbor and Terminal District.

 

-232-

Plaquemines – Amended & Restated Common Terms Agreement


Lenders” has the meaning given in Section 23.20 (No Fiduciary Duty) of the Common Terms Agreement.

Lenders’ Reliability Test” means a 90-day test which demonstrates that the LNG Facility’s overall production during the applicable time periods can meet the applicable minimum cumulative LNG production volumes without exceeding a maximum amount of allowable downtime, in accordance with and as more specifically set forth in Schedule O – 2 (Lenders’ Reliability Test Criteria) to the Common Terms Agreement or as otherwise agreed among the Borrower, the Facility Lenders and the Independent Engineer.

Letters of Credit” has the meaning given in the Credit Facility Agreement.

Lien” means any mortgage, privilege, pledge, lien, charge, assignment, assignment by way of security, hypothecation or security interest securing any obligation of any Person, any restrictive covenant or condition, right reservation, right to occupy, encroachment, option, easement, servitude, right of way or other imperfection of title or encumbrance (including matters that would be shown on an accurate survey) burdening any real property or any other agreement or arrangement having the effect of conferring security howsoever arising.

Lien Waiver” means any Lien waiver contemplated by any Material Construction Contract or Site Works Contract.

LNG” means Gas in a liquid state at or below its boiling point at a pressure of approximately one atmosphere.

LNG Buyer” means the buyer under the applicable LNG SPA.

LNG Facility” means the Phase 1 LNG Facility and the Phase 2 LNG Facility, collectively.

LNG Facility Site” means the portion of the Site on which the LNG Facility is situated, as more fully described in the applicable Real Property Documents.

LNG SPA” means an LNG sale and purchase agreement between the Borrower and a buyer of LNG pursuant to which the Borrower will sell and the buyer will purchase LNG from the Borrower.

LNG SPA Force Majeure” means “Force Majeure” as defined in each Initial LNG SPA (except the Excess Capacity LNG SPAs).

LNG SPA Mandatory Prepayment” has the meaning given in Section 8.2(a) (LNG SPA Mandatory Prepayment) of the Common Terms Agreement.

 

-233-

Plaquemines – Amended & Restated Common Terms Agreement


LNG SPA Prepayment Event” has the meaning given in Section 8.2(a) (LNG SPA Mandatory Prepayment) of the Common Terms Agreement.

Loan Facility Declared Default” means a Loan Facility Event of Default that is declared to be a default in accordance with Section 15.2 (Declaration of Loan Facility Declared Default) of the Common Terms Agreement.

Loan Facility Disbursement Accounts” are the Accounts described in Section 4.3(a)(i) (Accounts) of the Common Security and Account Agreement.

Loan Facility Event of Default” means any of the events set forth in Section 15.1 (Loan Facility Events of Default) of the Common Terms Agreement or any Obligor events of default under any Facility Agreement.

Loans” means the Senior Debt Obligations created under individual Facility Agreements to be made available by the Facility Lenders.

Local Accounts” has the meaning set forth in Section 4.12(a) (Local Accounts) of the Common Security and Account Agreement.

Louisiana Private Works Act” is the Louisiana Private Works Act, La. R.S. §§ 9:4801 et seq., and any successor provisions thereto.

LPS1” has the meaning given in the Phase 1 EPC Contract.

LPS1 Substantial Completion” means, in respect of LPS1, either (a) “LNG production system substantial completion” as defined in the Phase 1 EPC Contract or (b) that LPS1 has operated for a period of at least 30 consecutive days (which has been verified in writing by the Independent Engineer).

LPS2” has the meaning given in the Phase 1 EPC Contract.

LPS2 Substantial Completion” means, in respect of LPS2, either (a) “LNG production system substantial completion” as defined in the Phase 1 EPC Contract or (b) that LPS2 has operated for a period of at least 30 consecutive days (which has been verified in writing by the Independent Engineer).

LPS3” has the meaning given in the Phase 1 EPC Contract.

LPS3 Substantial Completion” means, in respect of LPS3, either (a) “LNG production system substantial completion” as defined in the Phase 1 EPC Contract or (b) that LPS3 has operated for a period of at least 30 consecutive days (which has been verified in writing by the Independent Engineer).

LPS4” has the meaning given in the Phase 1 EPC Contract.

 

-234-

Plaquemines – Amended & Restated Common Terms Agreement


LPS5” has the meaning given in the Phase 2 EPC Contract.

LPS5 Substantial Completion” means, in respect of LPS5, either (a) “LNG production system substantial completion” as defined in the Phase 2 EPC Contract or (b) that LPS5 has operated for a period of at least 30 consecutive days (which has been verified in writing by the Independent Engineer).

LPS6” has the meaning given in the Phase 2 EPC Contract.

Majority in Interest of the Senior Creditors” with respect to any Decision at any time means Senior Creditors:

 

  (a)

whose share in the outstanding principal amount of the Senior Debt Obligations and whose undrawn Senior Debt Commitments are more than 50% of all of the outstanding principal amount of the Senior Debt Obligations and all the undrawn Senior Debt Commitments of all the Senior Creditors; or

 

  (b)

if there is no principal amount of Senior Debt Obligations then outstanding, Senior Creditors whose Senior Debt Commitments are more than 50% of the aggregate Senior Debt Commitments of all Senior Creditors.

Mammoet” means Mammoet USA South, Inc.

Manager” means Venture Global Services, LLC.

Mandatory Prepayment Senior Notes Account” has the meaning given in Section 4.3(a)(xi) (Accounts) of the Common Security and Account Agreement.

Margin Stock” means margin stock as defined in Regulation U of the Federal Reserve Board.

Market Consultant” means IHS Markit or any independent replacement marketing consulting firm to be selected in accordance with Section 13.2 (Replacement and Fees) of the Common Terms Agreement.

Market Terms” means terms consistent with or no less favorable to the applicable Obligor (as seller or buyer, as the case may be) than either: (a) any Required LNG SPAs then in effect or (b) the terms a non-Affiliated seller or buyer, as the case may be, of the relevant product could receive in an arm’s-length transaction based on then-current market conditions for transactions of a similar nature and duration and taking into account such factors as the characteristics of the goods and services, the market for such goods and services (including any applicable regulatory conditions), tax effects of the transaction, the location of the Project Facilities and the counterparties.

 

-235-

Plaquemines – Amended & Restated Common Terms Agreement


Material Adverse Effect” means a material adverse effect on:

 

  (a)

each Obligor’s ability to perform and comply with its material obligations under each Material Project Agreement then in effect and to which it is a party;

 

  (b)

the Obligors’ ability, taken as a whole, to perform their material obligations under the Finance Documents;

 

  (c)

the Borrower’s ability to pay its Senior Debt Obligations when due;

 

  (d)

the Security Interests created by or under the relevant Security Documents, taken as a whole in respect of the Obligors or the Project Facilities, including the material impairment of the rights of or benefits or remedies, taken as a whole, available to the Secured Parties; or

 

  (e)

the Obligors’ financial condition and results of operation, on a consolidated basis.

Material Construction Contracts” means the Phase 1 Material Construction Contracts and the Phase 2 Material Construction Contracts.

Material Project Agreements” means the Phase 1 Material Project Agreements and the Phase 2 Material Project Agreements.

With respect to any Indenture, “Material Project Agreements” will have the meaning given in such Indenture.

Material Project Counterparties” means the Phase 1 Material Project Counterparties and the Phase 2 Material Project Counterparties.

Maturity Date” means May 25, 2029.

Minimum Insurance” means the insurance described in the Schedule of Minimum Insurance and required to be procured and maintained pursuant to Section 12.28 (Insurance Covenant) of the Common Terms Agreement.

Modification” means, with respect to any Finance Document, any amendment, supplement, waiver or other modification of the terms and provisions thereof and the term “Modify” shall have a corresponding meaning; provided, that with respect to Sections 7.2(b)(ii)(A), (B) and (C) (Modification Approval Levels – Modifications to Other Finance Documents) of the Common Security and Account Agreement, the exercise of any option, right or entitlement expressly set forth in the provisos to each such clause shall not be a Modification.

Moody’s” means Moody’s Investors Service, Inc. or any successor thereto.

 

-236-

Plaquemines – Amended & Restated Common Terms Agreement


Mortgage” means the Multiple Indebtedness Mortgage, Pledge of Leases and Rents and Security Agreement, from the Borrower to Venture Global LNG, Inc., as assigned on the Initial Closing Date to the Collateral Agent pursuant to that certain Assignment of Multiple Indebtedness Mortgage, Pledge of Leases and Rents and Security Agreement between Venture Global LNG, Inc. and the Collateral Agent in connection with that certain Assignment of Intercompany Loan Agreement among Venture Global LNG, Inc., the Borrower, the Guarantor and the Credit Facility Agent, as confirmed by that certain Confirmation of Multiple Indebtedness Mortgage, Pledge of Leases and Rents and Security Agreement by the Borrower in favor of the Collateral Agent and as confirmed by that certain Second Confirmation of Multiple Indebtedness Mortgage, Pledge of Leases and Rents and Security Agreement by the Borrower in favor of the Collateral Agent.

Mortgaged Property” has the meaning given in Section 4.1(t)(i) (Conditions to Initial Closing Date and Initial Advance – Flood Insurance) of the Common Terms Agreement.

MTPA” means million metric tonnes per annum.

Multiemployer Plan” means a “multiemployer plan” as defined in Section 3(37) of ERISA to which contributions have been made by any Obligor or any ERISA Affiliate in the past five years and which is covered by Title IV of ERISA.

Natural Gas Act” means the Natural Gas Act of 1938, 15 U.S.C. §717 et seq., as amended, and the regulations of FERC or DOE (as applicable) promulgated thereunder.

Net Cash Proceeds” means in connection with any asset disposition, the aggregate cash proceeds received by any Obligor in respect of any asset disposition (including any cash received upon the sale or other disposition of any non-cash consideration received in any asset disposition), net of the direct costs and expenses relating to such asset disposition and payments made to retire Indebtedness (other than the Senior Debt Obligations) required to be repaid in connection therewith, including legal, accounting and investment banking fees, and sales commissions, and any relocation expenses incurred as a result of such asset disposition, taxes paid or payable as a result of such asset disposition, in each case, after taking into account any available tax credits or deductions and amounts reserved for adjustment in respect of the sale price of such asset or assets established in accordance with GAAP.

New Facility Agent Accession Agreement (Additional Senior Debt)” has the meaning given in Section 19.4(b)(i) (Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement) of the Common Terms Agreement.

 

-237-

Plaquemines – Amended & Restated Common Terms Agreement


NFE” means NFE North Trading, LLC.

Non-Consenting Lender”, with respect to a Facility Agreement, has the meaning given in such Facility Agreement.

Non-Controlling Claimholders” means Senior Creditor Group Representatives who were not included in the Majority in Interest of the Senior Creditors who make up the Controlling Claimholders.

Non-FTA Authorization” means the Order Granting Long-Term, Multi-Contract Authorization to Export LNG to Non-Free Trade Agreement Nations issued by DOE/FE in FE Docket No. 16-28-LNG in its Order No. 4446 on October 16, 2019, as amended to extend the term in DOE/FE Order No. 4446-A issued on October 21, 2020.

Non-Recourse Parties” has the meaning given in Section 23.22 (Limited Recourse) of the Common Terms Agreement.

Non-Recourse Persons” has the meaning given in Section 10.3(a) (Limitation on Recourse) of the Common Security and Account Agreement.

Notice of Security Enforcement Action” has the meaning given in Section 6.2(f) (Initiation of Security Enforcement Action – Notice of Security Enforcement Action) of the Common Security and Account Agreement.

NYMEX” means the New York Mercantile Exchange, Inc., a wholly owned subsidiary of the CME Group Inc.

NYMEX Natural Gas Futures Contract” means the Futures Contract for natural gas on NYMEX, which is used for the physical receipt and/or delivery of gas at the Henry Hub located in Erath, Louisiana.

O&M Agreement” means (a) the agreement between the Borrower and the Operator for the relevant Project Facilities and (b) the agreement between the Guarantor and the Pipeline Operator for the relevant Project Facilities.

Obligors” means the Borrower and the Guarantor.

OFAC” means the Office of Foreign Assets Control of the US Department of the Treasury.

OFAC Laws” means any laws, regulations, and executive orders relating to the economic sanctions programs administered by OFAC, including the International Emergency Economic Powers Act, 50 U.S.C. sections 1701 et seq.; the Trading with the Enemy Act, 50 App. U.S.C. sections 1 et seq.; and the Office of Foreign Assets Control, Department of the Treasury Regulations, 31 C.F.R. Parts 500 et seq. (implementing the economic sanctions programs administered by OFAC).

 

-238-

Plaquemines – Amended & Restated Common Terms Agreement


OFAC SDN List” means the list of “Specially Designated Nationals and Blocked Persons” maintained by OFAC.

OID” has the meaning given in Section 6.2(a) (Working Capital Debt).

Operating Account” is the Account described in Section 4.3(a)(vii) (Accounts) of the Common Security and Account Agreement.

Operating Budget” has the meaning given in Section 10.5(a) (Operating Budget) of the Common Terms Agreement, it being acknowledged and understood that the “Operating Budget” will be comprised of a budget in respect of the LNG Facility and a budget in respect of the Gator Express Pipeline and that all references in the Finance Documents to the “Operating Budget” shall be to such budgets collectively or to the budget applicable to the Project Facilities that are the subject of the applicable provision, as the context may require.

Operating Manuals” means the operation, maintenance and spare parts manuals delivered by the EPC Contractor under the Phase 1 EPC Contract and the Phase 2 EPC Contract, as applicable.

Operation and Maintenance Expenses” means, for any period, computed without duplication, in each case, costs and expenses of the Obligors that are contemplated by the then-effective Operating Budget or are incurred in connection with any permitted excess thereunder pursuant to Section 12.3 (Project Construction; Maintenance of Properties) of the Common Terms Agreement including:

 

  (a)

fees and costs of the Manager pursuant to the Administrative Services Agreements; plus

 

  (b)

amounts payable by the Obligors under a Material Project Agreement then in effect; plus

 

  (c)

expenses for operating the Development and maintaining it in good repair and operating condition payable during such period, including the ordinary course fees and costs of the Operator and the Pipeline Operator payable pursuant to the O&M Agreements; plus

 

  (d)

LC Costs; plus

 

  (e)

insurance costs payable during such period; plus

 

  (f)

applicable sales and excise taxes (if any) payable or reimbursable by the Obligors during such period; plus

 

-239-

Plaquemines – Amended & Restated Common Terms Agreement


  (g)

franchise taxes payable by the Obligors during such period; plus

 

  (h)

property taxes payable by the Obligors during such period; plus

 

  (i)

any other direct taxes (if any) payable by the Obligors to the taxing authority (other than any taxes imposed on or measured by income or receipts) during such period; plus

 

  (j)

costs and fees attendant to the obtaining and maintaining in effect the Permits payable during such period; plus

 

  (k)

expenses for spares and other capital goods inventory, capital expenses related to the construction and start-up of the Project Facilities, maintenance capital expenditures, including those required to maintain the Project Facilities’ capacity; plus

 

  (l)

legal, accounting and other professional fees of the Obligors payable during such period; plus

 

  (m)

Required Capital Expenditures; plus

 

  (n)

the cost of purchase, storage and transportation of Gas and electricity; plus

 

  (o)

all other cash expenses payable by the Obligors in the ordinary course of business.

Operation and Maintenance Expenses shall exclude, to the extent included above: (i) transfers from any Account into any other Account (other than the Operating Account) during such period, (ii) payments of any kind with respect to Restricted Payments during such period, (iii) depreciation for such period, and (iv) except as provided in clauses (j), (k) and (m) above, any capital expenditure.

To the extent amounts are advanced in accordance with the terms of the applicable Senior Debt Instrument, secured Permitted Hedging Instrument or other Indebtedness permitted under Section 12.14 (Limitation on Indebtedness) of the Common Terms Agreement for the payment of such Operation and Maintenance Expenses, the obligation to repay such advances shall itself constitute an Operation and Maintenance Expense.

Operational” means (a) with respect to the Phase 1 LNG Facility, that all 12 of the blocks relating to the Phase 1 LNG Facility are mechanically complete, have passed the applicable acceptance tests and are operating in accordance with their performance guarantees, in each case, as set forth in the Phase 1 Material Construction Contracts, and (b) with respect to the Phase 2 LNG Facility, that the final 6 blocks relating to the Phase 2 LNG Facility are mechanically complete, have passed the applicable acceptance tests and are operating in accordance with their performance guarantees, in each case, as set forth in the Phase 2 Material Construction Contracts.

 

-240-

Plaquemines – Amended & Restated Common Terms Agreement


Operator” means Plaquemines LNG Operations, LLC, a limited liability company organized under the laws of the State of Delaware.

Original Common Security and Account Agreement” means the Common Security and Account Agreement, dated as of the Initial Closing Date, among the Borrower, the Guarantor, each Senior Creditor Group Representative on its own behalf and on behalf of the relevant Senior Creditor Group, the Intercreditor Agent, the Collateral Agent and the Account Bank.

Original Common Terms Agreement” means Common Terms Agreement, dated as of the Initial Closing Date, among the Borrower, the Guarantor, the Credit Facility Agent and each other Facility Agent on behalf of its respective Facility Lenders, and the Intercreditor Agent providing common representations, warranties, undertakings and events of default.

Original Credit Facility Agreement” means the Credit Facility Agreement, dated as of the Initial Closing Date, by and among the Borrower, the Guarantor, the Credit Facility Lender Parties party thereto from time to time, the Credit Facility Agent and, solely for purposes of Section 3.06 thereof, the Collateral Agent.

Original Finance Documents” means, together, each of the following documents:

 

  (a)

the Original Common Terms Agreement;

 

  (b)

the Original Common Security and Account Agreement;

 

  (c)

the Original Credit Facility Agreement;

 

  (d)

the Security Documents; provided, that for the purposes of this definition of “Original Finance Documents”, “Common Security and Account Agreement” and “Finance Document” as used in the definition of “Security Documents” shall refer to the Original Common Security and Account Agreement and the Original Finance Documents;

 

  (e)

the Direct Agreements in place as of the Initial Closing Date;

 

  (f)

the Original Intercreditor Agreement;

 

  (g)

any fee letters with parties providing financing (other than any Equity Funding) in place as of the Initial Closing Date; and

 

-241-

Plaquemines – Amended & Restated Common Terms Agreement


  (h)

any Permitted Senior Debt Hedging Instrument in place prior to the Upsize Closing Date; provided that as used in Section 4.1(a) (Conditions to Initial

Closing Date and Initial Advance), such term shall refer only to any Permitted Senior Debt Hedging Instrument in place as of the Initial Closing Date.

Original Intercreditor Agreement” means the Intercreditor Agreement, dated as of the Initial Closing Date, among the Intercreditor Agent, the Collateral Agent and the Facility Agents and Hedging Banks party thereto from time to time, setting forth the appointment of the Intercreditor Agent and setting forth voting and certain intercreditor arrangements among all Facility Lenders and Hedging Banks.

Other Connection Taxes” means, with respect to any Finance Party, Taxes imposed as a result of a present or former connection between such Finance Party and the jurisdiction imposing such Tax (other than connections arising solely from such Finance Party having executed, delivered, become a party to, performed its obligations under, received payments under, received or perfected a security interest under, sold or assigned an interest in, or engaged in any other transaction pursuant to or enforced any Finance Document).

Other Taxes” means all present or future stamp, court or documentary, intangible, recording, filing or similar Taxes that arise from any payment made under, from the execution, delivery, performance, enforcement or registration of, from the receipt or perfection of a security interest under, or otherwise with respect to, any Finance Document (other than any Indenture or Senior Notes), except any such Taxes that are Other Connection Taxes imposed with respect to an assignment of a Facility Lender’s interest in a Facility Agreement (other than an assignment made pursuant to Section 19.5 (Mitigation Obligations; Replacement of Lenders) of the Common Terms Agreement).

Parent Guarantees” means the Phase 1 Parent Guarantees and the Phase 2 Parent Guarantees.

Participant” means each Person (other than a natural Person, or a holding company, investment vehicle or trust for, or owned and operated for the primary benefit of, a natural Person) to whom a Facility Lender may sell participations from time to time.

Participant Register” means a register on which each Facility Lender which sells a participation, enters the name and address of each Participant and the principal amounts (and stated interest) of each Participant’s interest in the relevant Facility Agreement or other obligations under the Finance Documents. Each Facility Lender that sells a participation shall, acting solely for this purpose as a non-fiduciary agent of the Borrower, maintain a Participant Register.

Parties” means, with respect to any agreement, the signatories to such agreement.

 

-242-

Plaquemines – Amended & Restated Common Terms Agreement


Patent Licenses” means all agreements, licenses and covenants providing for the granting of any right in or to any Patent or otherwise providing for a covenant not to sue for infringement or other violation of any Patent (whether an Obligor is licensee or licensor thereunder) including each agreement required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Patent Licenses” (as such schedule may be amended or supplemented from time to time).

Patents” means all United States and foreign and multinational patents and certificates of invention, or similar industrial property rights, and applications for any of the foregoing, including:

 

  (a)

each patent and patent application required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Patents” (as such schedule may be amended or supplemented from time to time);

 

  (b)

all reissues, substitutes, divisions, continuations, continuations-in-part, extensions, renewals, and reexaminations thereof;

 

  (c)

all inventions and improvements described and claimed therein;

 

  (d)

all rights to sue or otherwise recover for any past, present and future infringement or other violation thereof;

 

  (e)

all proceeds of the foregoing, including license fees, royalties, income, payments, claims, damages, and proceeds of suit now or hereafter due and/or payable with respect thereto; and

 

  (f)

all other rights of any kind accruing thereunder or pertaining thereto throughout the world.

Payment Date” means each CTA Payment Date and any other date for payment of Senior Debt Obligations (including payment dates for the payment of interest) under or pursuant to any Senior Debt Instrument, including any Indenture, or Permitted Hedging Instrument.

Payment Default” means any event of default under Section 15.1(a) (Loan Facility Events of Default – Payment Default) of the Common Terms Agreement and any comparable provision in any Senior Debt Instrument then in effect entered into after the date of the Common Security and Account Agreement.

PBGC” means the Pension Benefit Guaranty Corporation established pursuant to Subtitle A of Title IV of ERISA (or any successor).

 

-243-

Plaquemines – Amended & Restated Common Terms Agreement


Pension Plan” means a Plan, other than a Multiemployer Plan, which is subject to Title IV of ERISA or Section 412 of the Code or Section 302 of ERISA.

Performance Liquidated Damages” means any liquidated damages resulting from the Project Facilities’ performance that are required to be paid by a Construction Contractor or any other counterparty to a Material Project Agreement for or on account of any diminution to the performance of the Project Facilities.

Performance Test” has the meaning given to such term in each applicable Material Construction Contract.

Permit” means (a) any authorization, consent, approval, license, lease, ruling, tariff, rate, certification, waiver, exemption, filing, variance, claim, order, judgment or decree of, by or with, (b) any required notice to, (c) any declaration of or with, or (d) any registration by or with, in the cases of the foregoing clauses (a) through (d), any Governmental Authority and then required for the development, construction and operation of the Project Facilities as contemplated in the Finance Documents and the Material Project Agreements then in effect.

Permitted Additional Working Capital Debt” means any additional working capital debt incurred pursuant to Section 6.2 (Working Capital Debt); provided that,

(1) no Event of Default or Unmatured Event of Default has occurred and is Continuing or could reasonably be expected to occur after giving effect to the incurrence of the Working Capital Debt and (2) any Senior Debt Instrument governing the additional working capital debt shall require the Borrower to reduce the principal amount relating to any revolving Loans thereunder to $0 for a period of at least five consecutive Business Days at least once per calendar year.

Permitted Completion Amount” means a sum equal to an amount certified by the Borrower (and confirmed reasonable by the Independent Engineer) on the Project Phase 2 Completion Date as necessary to pay 125% of the Permitted Completion Costs.

Permitted Completion Costs” means unpaid Project Costs (including Project Costs not included in the Construction Budget and Schedule delivered on the Upsize Closing Date) that the Borrower reasonably anticipates will be required for the Project Facilities to pay all remaining costs associated with outstanding Punch List Items (as defined in the Material Construction Contracts) work, retainage, fuel incentive payments, disputed amounts, start-up costs, bonuses and other costs required under the Material Construction Contracts.

Permitted Development Expenditures” means Development Expenditures that:

 

-244-

Plaquemines – Amended & Restated Common Terms Agreement


  (a)

are required by applicable law or regulations, any consent from a Governmental Authority, Industry Standards or Prudent Industry Practice applicable to the Development;

 

  (b)

are otherwise used for the Development; or

 

  (c)

are otherwise used for an Expansion permitted in accordance with Section 7.2 (Expansion Contracts) of the Common Terms Agreement; and

are funded from (i) Equity Funding not otherwise committed to other expenditure for the Development, (ii) Insurance Proceeds and Condemnation Proceeds to the extent permitted by Article 5 (Insurance and Condemnation Proceeds and Performance Liquidated Damages) of the Common Security and Account Agreement or proceeds of dispositions to the extent permitted by Section 12.17 (Sale of Project Property) of the Common Terms Agreement or any equivalent provision of any other Senior Debt Instrument and (iii) Retained Excess Cash Flow, in the case of each of the foregoing sub-clauses (i), (ii) and (iii), in each case as expressly permitted under the Finance Documents and which use for the contemplated development could not reasonably be expected to have a Material Adverse Effect.

Permitted Finance Costs” means, for any period, the sum of all amounts of principal, interest, fees and other amounts payable in relation to Indebtedness (other than Senior Debt and other than LC Costs and other amounts payable in relation to Indebtedness that constitute Operation and Maintenance Expenses) permitted by Section 12.14(b) (Limitation on Indebtedness) (including guarantees thereof permitted under Section 12.15 (Guarantees) of the Common Terms Agreement during such period) plus all amounts payable during such period pursuant to Permitted Hedging Instruments that are not secured, plus any amounts required to be deposited in margin accounts pursuant to Permitted Hedging Instruments; provided that Permitted Finance Costs will not include funds categorized as Operation and Maintenance Expenses under the last sentence of the definition thereof.

Permitted Finance Costs Reserve Account” is the account described in Section 4.3(a)(xiii) (Accounts) of the Common Security and Account Agreement.

Permitted Hedging Instrument” means (a) each Initial Permitted Senior Debt Hedging Instrument; (b) each Upsize Permitted Senior Debt Hedging Instrument or (c) a Hedging Instrument entered into by the Borrower in the ordinary course of business, including any Hedging Instrument entered into in connection with forward sale or factoring contracts related to Pre-Completion Revenues, and that (i) is with a Hedging Bank or a Gas Hedge Provider, and (ii) is entered for non- speculative purposes and is on arm’s-length terms; provided that if such Hedging Instrument is a Gas Hedging Instrument, it is for a period not to exceed the three

 

-245-

Plaquemines – Amended & Restated Common Terms Agreement


prompt month contracts (or in the case of Basis Swaps, thirty six months) and the aggregate quantum under all (1) Futures Contracts, Fixed-Floating Futures Swaps, NYMEX Natural Gas Futures Contracts and Swing Swaps does not exceed 50 TBtu, (2) Index Swaps does not exceed 23.25 TBtus, and (3) Basis Swaps does not exceed 23.25 TBtus, where the limitations in each of the categories described in sub-clauses (1), (2) and (3) are not aggregated. “Permitted Hedging Instrument” includes any “Permitted Senior Debt Hedging Instrument.” For the avoidance of doubt, each Anticipatory Hedge shall constitute (i) a Permitted Hedging Instrument and (ii) upon the relevant counterparty acceding to the Common Security and Account Agreement, a Permitted Senior Debt Hedging Instrument, in each case for all purposes hereunder and under the other Transaction Documents. As used in the preceding sentence, “Anticipatory Hedge” means any interest rate transaction between a Hedging Bank and Venture Global LNG, Inc. or the Borrower entered into prior to the Initial Closing Date, and any Hedging Instrument entered into between a Hedging Bank and the Borrower, which results from an assignment, novation, participation, or any other conveyance or transfer of an Anticipatory Hedge (including any restructuring thereof or offsetting transactions related thereto) to the Borrower.

Permitted Hedging Liabilities” means all present and future liabilities (actual or contingent) payable or owing by an Obligor under Permitted Hedging Instruments (including the obligation to pay a Hedging Termination Amount) together with:

 

  (a)

any novation, deferral or extension of any of those liabilities;

 

  (b)

any claim for damages or restitution arising out of, by reference to or in connection with any of those liabilities;

 

  (c)

any claim flowing from any recovery by an Obligor or a receiver or liquidator thereof or any other Person of a payment or discharge in respect of any of those liabilities on grounds of preference or otherwise; and

 

  (d)

any amounts (such as post-insolvency interest) which could be included in any of the above but for any discharge, non-provability, unenforceability or non-allowability of the same in any insolvency or other proceedings.

Permitted Liens” means:

 

  (a)

Liens for taxes not delinquent or being contested in good faith and by appropriate proceedings in relation to which appropriate reserves are maintained and liens for customs duties that have been deferred in accordance with the laws of any applicable jurisdiction;

 

-246-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

deposits or pledges to secure obligations under workmen’s compensation, old age pensions, social security or similar laws or under unemployment insurance;

 

  (c)

deposits or other financial assurances to secure bids, tenders, contracts (other than for borrowed money), leases, concessions, licenses, statutory obligations, surety and appeal bonds (including any bonds permitted under the Material Construction Contracts), performance bonds and other obligations of like nature arising in the ordinary course of business and cash deposits incurred in connection with natural gas purchases;

 

  (d)

mechanics’, workmen’s, materialmen’s, suppliers’, warehouse, Liens of lessors and sublessors or other like Liens arising or created in the ordinary course of business with respect to obligations that are not due or that are being contested in good faith;

 

  (e)

servitudes, easements, rights of way, encroachments and other similar encumbrances burdening the Project Facilities’ land that are granted in the ordinary course, imperfections of title on real property, and restrictive covenants, zoning restrictions, licenses or conditions on the grant of real property (in relation to such real property); provided that such servitudes, easements, rights of way, encroachments and other similar encumbrances, imperfections, restrictive covenants, restrictions, licenses or conditions do not materially interfere with the Development as contemplated in the Finance Documents and the Material Project Agreements or have a material adverse effect on the Security Interests;

 

  (f)

Liens to secure Indebtedness permitted by Sections 12.14(i) and (q) (Limitation on Indebtedness) of the Common Terms Agreement;

 

  (g)

the Security Interests;

 

  (h)

Liens in the ordinary course of business arising from or created by operation of applicable law or required in order to comply with any applicable law and that could not reasonably be expected to cause a Material Adverse Effect or materially impair the Development’s use of the encumbered assets;

 

  (i)

Liens in the ordinary course of business over any assets (the aggregate value of which assets at the time any such Lien is granted does not exceed $75 million) that could not reasonably be expected to cause a Material Adverse Effect or materially impair the Development’s use of the encumbered assets;

 

-247-

Plaquemines – Amended & Restated Common Terms Agreement


  (j)

contractual or statutory rights of set-off (including netting) granted to the Obligors’ bankers, under any Permitted Hedging Instrument or any Material Project Agreement and that could not reasonably be expected to cause a Material Adverse Effect;

 

  (k)

deposits or other financial assurances to secure reimbursement or indemnification obligations in respect of letters of credit or in respect of letters of credit put in place by an Obligor and payable to suppliers, service providers, insurers or landlords in the ordinary course of business;

 

  (l)

Liens that are scheduled exceptions to the coverage afforded by a Title Policy on the Upsize Closing Date or later date of amendment of a Title Policy or delivery of a new Title Policy;

 

  (m)

legal or equitable encumbrances (other than any attachment prior to judgment, judgment lien or attachment in aid of execution on a judgment) deemed to exist by reason of the existence of any pending litigation or other legal proceeding if the same is effectively stayed or the claims secured thereby are being contested in good faith and by appropriate proceedings and an appropriate reserve has been established in respect thereof in accordance with GAAP;

 

  (n)

the Liens created pursuant to the Real Property Documents;

 

  (o)

Liens created by any fee owner under a Lease, to the extent permitted by such Lease;

 

  (p)

Liens by any Obligor in favor of any other Obligor; and

 

  (q)

Liens arising out of judgments or awards not constituting an Event of Default so long as an appeal or proceeding for review is being prosecuted in good faith and for the payment of which adequate cash reserves, bonds or other cash equivalent security have been provided or are fully covered by insurance (other than any customary deductible).

Permitted Payments” means, without duplication as to amounts allowed to be distributed under any other provision of the Common Terms Agreement:

 

  (a)

payments to an Affiliate of the Borrower to permit such Affiliate to pay its reasonable accounting, legal and administrative expenses when due, in an aggregate amount not to exceed $10 million per calendar year (escalating annually in accordance with the applicable Material Project Agreements); and

 

-248-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

with respect to any periods (or portions thereof), the amount sufficient to permit pro rata distributions to each direct or indirect equity holder of the Obligors to pay U.S. federal, state, local or non-U.S. income or similar Taxes (including estimated taxes) attributable to its direct or indirect interests in the Obligors for each taxable year, as reasonably determined by the Obligors (a) utilizing an assumed tax rate equal to the highest combined marginal U.S. federal, state and local income tax rate applicable to an individual resident in, or a corporation doing business in, the State of New York, whichever is higher, and (b)(1) taking into account the character of income (e.g., as ordinary or capital gain), (2) taking into account Medicare taxes under Section 1411 of the Code, (3) taking into account any applicable limitations with respect to deductions, and (4) ignoring the effects of Sections 199A, 734 and 743 of the Code.

Permitted Senior Debt Hedging Instrument” means a Permitted Hedging Instrument in respect of which the Hedging Banks has acceded to the Common Security and Account Agreement.

Permitted Senior Debt Hedging Liabilities” means all present and future liabilities (actual or contingent) payable or owing by an Obligor under Permitted Senior Debt Hedging Instruments (including the obligation to pay a Senior Debt Hedging Termination Amount) together with:

 

  (a)

any novation, deferral or extension of any of those liabilities;

 

  (b)

any claim for damages or restitution arising out of, by reference to or in connection with any of those liabilities;

 

  (c)

any claim flowing from any recovery by an Obligor or a receiver or liquidator thereof or any other Person of a payment or discharge in respect of any of those liabilities on grounds of preference or otherwise; and

 

  (d)

any amounts (such as post-insolvency interest) which would be included in any of the above but for any discharge, non-provability, unenforceability or non-allowability of the same in any insolvency or other proceedings.

“Person” means any individual, firm, corporation, partnership, joint venture, association, trust, unincorporated organization, Governmental Authority or other entity whether enjoying legal personality or not, and includes its successors or permitted assignees.

Petronas” means Petronas LNG Ltd.

PGNIG” means PKN Orlen S.A. (fka Polskie Górnictwo Naftowe I Gazownictwo Spółka Akcyjna).

P2 WCF Sublimit” has the meaning given in Section 6.2(a) (Working Capital Debt).

 

-249-

Plaquemines – Amended & Restated Common Terms Agreement


Phase 1 Construction Contractors” means the EPC Contractor, the Pipeline Contractors, BHES, UOP, Weeks-Massman, CB&I and Mammoet.

Phase 1 EPC Contract” means the Second Amended and Restated Engineering, Procurement and Construction Agreement, dated as of January 7, 2022, by and between the Borrower and EPC Contractor as supplemented by the Limited Notice to Proceed, dated as of January 12, 2022, Addendum No. 1 to Limited Notice to Proceed, dated as of April 1, 2022, Addendum No. 2 to Limited Notice to Proceed, dated as of May 1, 2022, and Notice to Proceed, dated as of May 25, 2022, and as amended by Change Order No. 1 dated as of May 17, 2022, Change Order No. 2, dated as of May 20, 2022, Change Order No. 3 dated as of September 30, 2022, Change Order No. 4 dated as of October 12, 2022, and Change Order No. 5, dated as of March 2, 2023, and as amended by Amendment No.1 to Second Amended and Restated Engineering, Procurement and Construction Agreement, dated October 11, 2022, Amendment No.2 to Second Amended and Restated Engineering, Procurement and Construction Agreement, dated February 1, 2023, together with each Phase 1 EPC Contract Guaranty.

Phase 1 EPC Contract Guaranty” means each of (i) the Guaranty, dated as of April 21, 2021, by KBR, Inc. for the benefit of the Borrower and (ii) the Guaranty, dated as of April 21, 2021, by Zachry Holdings, Inc. for the benefit of the Borrower.

Phase 1 Excess Capacity LNG SPA” means the LNG Sales and Purchase Agreement (FOB) (Phase 1), dated as of September 14, 2021, by and between the Borrower and Venture Global Commodities, LLC, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of February 3, 2022, and Amendment No. 2 to LNG Sales and Purchase Agreement (FOB), dated as of April 12, 2022.

Phase 1 Initial LNG Buyers” means EDF, Sinopec, CNOOC, Shell and PGNIG.

Phase 1 Initial LNG SPA Guarantees” means:

(a) the Parent Company Guarantee, dated as of December 21, 2021, by CNOOC Gas and Power Group Co., Ltd. in favor of the Borrower;

(b) Guarantee, dated as of March 1, 2022, by Shell USA, Inc. in favor of the Borrower; and

(c) Any other guarantee delivered to the Borrower under a Phase 1 Initial LNG SPA.

Phase 1 Initial LNG SPAs” means the following LNG SPAs entered into between the Borrower and the Phase 1 Initial LNG Buyers or Venture Global Commodities, LLC, as applicable, on or before the Initial Closing Date:

 

-250-

Plaquemines – Amended & Restated Common Terms Agreement


  (a)

LNG Sales and Purchase Agreement (FOB), dated as of September 28, 2018, by and between the Borrower and PGNIG, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of June 12, 2019, and Amendment No. 2 to LNG Sales and Purchase Agreement (FOB), dated as of September 2, 2021, and as supplemented by the Letter, dated as of June 25, 2021, the Letter, dated as of November 22, 2021 and the Letter, dated as of March 11, 2022;

 

  (b)

LNG Sales and Purchase Agreement (FOB), dated as of February 24, 2020, by and between the Borrower and EDF, as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of March 11, 2022 and as supplemented by the Letter, dated as of November 9, 2020, and as amended by Amendment No. 2 to LNG Sales and Purchase Agreement (FOB), dated as of May 25, 2022;

 

  (c)

LNG Sales and Purchase Agreement (FOB), dated as of September 1, 2021, by and between the Borrower and Sinopec, as supplemented by the Letter, dated as of September 28, 2021 and the Letter, dated as of March 15, 2022 and as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (FOB), dated as of May 18, 2022;

 

  (d)

LNG Sales and Purchase Agreement (DPU), dated as of September 1, 2021, by and between the Borrower and Sinopec, as supplemented by the Letter, dated as of September 28, 2021 and the Letter, dated as of March 15, 2022 and as amended by Amendment No. 1 to LNG Sales and Purchase Agreement (DPU), dated as of May 18, 2022;

 

  (e)

LNG Sales and Purchase Agreement (FOB), dated as of December 9, 2021, by and between the Borrower and CNOOC, as supplemented by the Letter, dated as of March 15, 2022;

 

  (f)

LNG Sales and Purchase Agreement (FOB), dated as of February 25, 2022, by and between the Borrower and Shell; and

 

  (g)

the Phase 1 Excess Capacity LNG SPA.

Phase 1 Lenders’ Reliability Test” means a 90-day test which demonstrates that the Phase 1 Project Facilities’ overall production during the applicable time periods can meet the applicable minimum cumulative LNG production volumes without exceeding a maximum amount of allowable downtime, in accordance with and as more specifically set forth in Schedule O – 1 (Phase 1 Lenders’ Reliability Test Criteria) to the Common Terms Agreement or as otherwise agreed among the Borrower, the Facility Lenders and the Independent Engineer.

 

-251-

Plaquemines – Amended & Restated Common Terms Agreement


Phase 1 LNG Facility” means the approximately 13.33 MTPA nameplate first phase of the Project, consisting of twelve integrated single mixed refrigerant liquefaction blocks and supporting facilities, four natural gas pre-treatment units (each capable of supporting approximately 5.0 MTPA of LNG production capacity), two 200,000 cubic meter cryogenic LNG storage tanks, a marine terminal with two LNG berthing docks that can accommodate vessels up to at least 200,000 cubic meters in capacity, and a nominal 611 megawatt (720 megawatt peak) inside the fence, air-cooled combined-cycle gas-fired power plant with an approximately 255 megawatt of additional gas-fired turbine power generation, in each case (i) with related onsite utilities and supporting infrastructure and (ii) as such facilities may be improved, replaced, modified, changed or expanded in accordance with the Finance Documents.

Phase 1 LNG Facility Date Certain” means February 28, 2027; provided that if, on or prior to February 28, 2027, the Borrower certifies to the Intercreditor Agent (and the Independent Engineer reasonably concurs with such certification in writing) that (i) the only remaining condition to the Project Phase 1 Completion Date as of the date of delivery of such certification, other than conditions that can only be satisfied on the Project Phase 1 Completion Date, is the condition specified in Section 14.1(c)(iii) (Conditions to Occurrence of the Project Phase 1 Completion Date – Physical Completion Certificate) and (ii) the Phase 1 Lenders’ Reliability Test has commenced in accordance with the procedures specified in Section 12.11 (Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages) and the Independent Engineer reasonably expects the Phase 1 Lenders’ Reliability Test to be completed on or prior to May 29, 2027, then for all purposes under this Agreement the “Phase 1 LNG Facility Date Certain” means May 29, 2027.

Phase 1 LTS Purchase Order” means that certain Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of January 19, 2022, by and between Borrower and BHES, as amended by Change Order No. 1 under the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of September 30, 2021, Change Order No. 2 under the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of February 25, 2022 and Change Order No. 3 under the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of October 24, 2022, and as supplemented by Limited Notice to Proceed Under the Purchase Order Contract for the Sale of Liquefaction Train System, dated as of September 30, 2021, Full Notice to Proceed Under the Amended and Restated Purchase Order Contract for the Sale of Liquefaction Train System, dated as of February 25, 2022, issued by Borrower, Letter Agreement re: UOP Pre-Treatment System, dated as of December 22, 2021 and Letter Agreement re: UOP Pre- Treatment System, dated as of May 23, 2022.

 

-252-

Plaquemines – Amended & Restated Common Terms Agreement


Phase 1 Marine Works Construction Agreement” means that certain Construction Agreement Relating to Marine Works, dated as of October 8, 2021, by and between the Borrower and Weeks-Massman, as supplemented by Anticipated LNTP, dated as of October 11, 2021, issued by the Borrower and Notice to Proceed, dated as of March 14, 2022, as amended by Change Order No. 1 dated as of October 11, 2022 and Change Order No. 2 dated as of January 31, 2023.

Phase 1 Material Construction Contracts” means, together, each of the following documents:

 

  (a)

the Phase 1 EPC Contract;

 

  (b)

the Pipeline Construction Contracts;

 

  (c)

the Phase 1 LTS Purchase Order;

 

  (d)

the PIS 2021 Purchase Order;

 

  (e)

the PIS 2022 Purchase Order;

 

  (f)

the Phase 1 Pretreatment Contract;

 

  (g)

the Phase 1 Marine Works Construction Agreement;

 

  (h)

the Construction Dock and Marine Offloading Facilities Construction Agreement;

 

  (i)

the Storm Surge Wall Construction Agreement;

 

  (j)

the Phase 1 Storage Tanks EPC Contract; and

 

  (k)

the Bridge Lease Agreement.

Phase 1 Material Project Agreements” means:

 

  (a)

the Phase 1 Initial LNG SPAs (except the Phase 1 Excess Capacity LNG SPA);

 

  (b)

the Phase 1 Initial LNG SPA Guarantees;

 

  (c)

the Phase 1 Material Construction Contracts;

 

  (d)

the Gas Transportation Agreements;

 

  (e)

the Service Agreements (other than the agreement described in clauses (g), (h) and (i) of the definition thereof);

 

-253-

Plaquemines – Amended & Restated Common Terms Agreement


  (f)

from and after the entry into such agreement, the agreement described in clause (g), (h) and (i) of the definition of “Service Agreements”;

 

  (g)

the Site Works Contracts;

 

  (h)

the Leases;

 

  (i)

the Phase 1 Parent Guarantees;

 

  (j)

prior to the Project Phase 2 Completion Date, the Access License Agreements;

 

  (k)

the Pipeline Service Agreements; and

 

  (l)

any Subsequent Material Project Agreement with respect to the Phase 1 Project Facilities,

provided, however, that the Supplemental Phase 1 LNG SPA shall not be a Phase 1 Material Project Agreement and that any Phase 1 Material Project Agreement shall cease to be a Phase 1 Material Project Agreement when all material obligations thereunder have been performed and paid in full.

Phase 1 Material Project Counterparties” means each of the Phase 1 Construction Contractors, the Phase 1 Initial LNG Buyers, CNOOC Gas and Power Group Co., Ltd., Shell USA, Inc., Texas Eastern Transmission, LP, Tennessee Gas Pipeline Company, L.L.C., Columbia Gulf Transmission, LLC, Baker Hughes Holdings LLC, General Electric Company, McDermott International, Ltd., Honeywell International Inc., KBR, Inc., Zachry Holdings, Inc., Plaquemines Tug Services, LLC, the Manager, the Operator, the Pipeline Operator, WT Byler Co., Inc., Remedial Construction Services, L.P., ENTACT Environmental Services, Inc., The Plaquemines Port Harbor and Terminal District, Plaquemines Land Ventures, LLC and each other party (other than an Obligor) to a Phase 1 Material Project Agreement.

Phase 1 Parent Guarantees” means:

 

  (a)

Guaranty Agreement, dated as of February 26, 2021, by Baker Hughes Holdings LLC for the benefit of the Borrower, relating to the Phase 1 LTS Purchase Order;

 

  (b)

Parent Guaranty Agreement, dated as of March 26, 2021, by General Electric Company for the benefit of BHES and the Borrower, relating to the PIS 2021 Purchase Order;

 

-254-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

Guaranty Agreement, dated as of February 26, 2021, by Baker Hughes Holdings LLC for the benefit of the Borrower, relating to the PIS 2021 Purchase Order;

 

  (d)

Guaranty Agreement, dated as of February 8, 2022, by Baker Hughes Holdings LLC for the benefit of the Borrower, relating to the PIS 2022 Purchase Order;

 

  (e)

Parent Guaranty Agreement, dated as of February 24, 2022, by General Electric Company for the benefit of BHES and the Borrower, as supplemented by Letter Agreement, dated as of February 24, 2022, by and between General Electric Company, BHES and the Borrower, relating to the PIS 2022 Purchase Order;

 

  (f)

Parent Guarantee, dated as of April 12, 2019, by McDermott International, Ltd. (as assignee of McDermott International, Inc.), in favor of the Borrower, as assigned pursuant to the Assignment, Assumption, and Amendment Agreement, dated as of November 8, 2021, by and among McDermott International, Inc., McDermott International, Ltd., the Borrower and CB&I;

 

  (g)

Parent Guarantee (Phase 1), dated as of April 12, 2019, by Honeywell International Inc. in favor of the Borrower;

 

  (h)

Parent Guarantee, dated as of March 11, 2022, by Keller Holdings, Inc. in favor of the Borrower; and

 

  (i)

each Phase 1 EPC Contract Guaranty.

Phase 1 Pre-Completion Revenues Account” is the account described in Section 4.3(a)(iii) (Accounts) of the Common Security and Account Agreement.

Phase 1 Pretreatment Contract” means that certain Second Amended and Restated Engineering and Procurement Agreement (Phase 1), dated as of December 23, 2021, by and between the Borrower and UOP, as amended by Change Order No. 1, dated as of August 26, 2022 and as supplemented by Limited Notice to Proceed No. 1, dated as of September 27, 2021, Anticipated LNTP, dated as of November 16, 2021, and Notice to Proceed, dated April 29, 2022, together with that certain Second Amended and Restated Natural Gas Integrated Pretreatment Block License Agreement (Phase 1), dated as of December 23, 2021, by and between the Borrower and UOP.

Phase 1 Project Facilities” means the Phase 1 LNG Facility and the Gator Express Pipeline, as such facilities may be repaired and replaced from time to time or modified, changed or expanded as permitted in the Finance Documents.

 

-255-

Plaquemines – Amended & Restated Common Terms Agreement


Phase 1 Punch List Amount” means not less than 125% of any punch list items in respect of the Phase 1 Project Facilities.

Phase 1 Reserve Amounts” has the meaning given in Section 14.1(e) (Conditions to Occurrence of the Project Phase 1 Completion Date – Payment).

Phase 1 Storage Tanks EPC Contract” means that certain LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 1), dated as of April 12, 2019, by and between the Borrower and CB&I, as amended by Amendment No. 1 to LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 1), dated as of June 30, 2020, Amendment No. 2 to LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 1), dated as of August 13, 2020, Amendment No. 3 to LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 1), dated as of September 3, 2020, Amendment No. 4 to LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 1), dated as of September 17, 2020, Amendment No. 5, dated as of December 2, 2022, and Change Order No. 1, dated as of November 16, 2021, Change Order No. 2, dated as of March 17, 2022, and Change Order No. 3, dated as of August 8, 2022, and as supplemented by Limited Notice to Proceed No. 1, dated as of September 25, 2020, Notice to Proceed, dated as of September 30, 2021, and Waiver, dated as of November 2, 2021.

Phase 2 Construction Contractors” means the EPC Contractor, BHES, UOP, Weeks-Massman, and CB&I.

Phase 2 EPC Contract” means the Engineering, Procurement and Construction Agreement (Phase 2), dated as of January 10, 2023, by and between the Borrower and EPC Contractor, as supplemented by the Limited Notice to Proceed, dated as of January 23, 2023, together with each Phase 2 EPC Contract Guaranty.

Phase 2 EPC Contract Guaranty” means each of (i) the Guaranty, dated as of January 10, 2023, by KBR, Inc. for the benefit of the Borrower and (ii) the Guaranty, dated as of January 10, 2023, by Zachry Holdings, Inc. for the benefit of the Borrower.

Phase 2 Excess Capacity LNG SPA” means the LNG Sales and Purchase Agreement (FOB) (Phase 2), dated as of September 14, 2021, by and between Borrower and Venture Global Commodities, LLC, as amended by Amendment No. 1 thereto dated as of September 22, 2022.

Phase 2 Initial LNG Buyers” means NFE, Petronas, Exxon, ENBW, Chevron, China Gas and Excelerate.

Phase 2 Initial LNG SPA Guarantees” means:

 

-256-

Plaquemines – Amended & Restated Common Terms Agreement


  (a)

Guarantee, dated as of March 2, 2022, by New Fortress Energy Inc. in favor of Borrower;

 

  (b)

Guarantee, dated as of February 21, 2023, by China Gas Holdings Limited in favor of the Borrower;

 

  (c)

Guarantee, dated as of February 22, 2023, by Excelerate Energy Limited Partnership in favor of the Borrower; and

 

  (d)

any other guarantee delivered to the Borrower under a Phase 2 Initial LNG SPA.

Phase 2 Initial LNG SPAs” means the following LNG SPAs entered into between the Borrower and the Phase 2 Initial LNG Buyers or Venture Global Commodities, LLC, as applicable, on or before the Upsize Closing Date:

 

  (a)

LNG Sales and Purchase Agreement (FOB), dated as of March 2, 2022, by and between Borrower and NFE;

 

  (b)

LNG Sales and Purchase Agreement (FOB), dated as of April 29, 2022, by and between Borrower and Petronas;

 

  (c)

LNG Sales and Purchase Agreement (FOB), dated as of April 29, 2022, by and between Borrower and Exxon;

 

  (d)

LNG Sales and Purchase Agreement (FOB), dated as of June 10, 2022, by and between Borrower and ENBW, as modified by the Notice of ACQ Increase dated September 29, 2022;

 

  (e)

LNG Sales and Purchase Agreement (FOB), dated as of June 15, 2022, by and between Borrower and Chevron;

 

  (f)

LNG Sales and Purchase Agreement (FOB), dated as of February 21, 2023, by and between Borrower and China Gas;

 

  (g)

LNG Sales and Purchase Agreement (FOB), dated as of February 22, 2023, by and between the Borrower and Excelerate; and

 

  (h)

the Phase 2 Excess Capacity LNG SPA.

Phase 2 LNG Facility” means the approximately 6.67 MTPA nameplate second phase of the Project, consisting of six integrated single mixed refrigerant liquefaction blocks and supporting facilities, two natural gas pre-treatment units (each capable of supporting 5.0 MTPA of LNG production capacity), two 200,000 cubic meter cryogenic LNG storage tanks, one LNG berthing dock that can accommodate vessels up to at least 200,000 cubic meters in capacity, and the

 

-257-

Plaquemines – Amended & Restated Common Terms Agreement


balance of a nominal 611 megawatt (720 megawatt peak) inside-the-fence, air- cooled combined-cycle gas-fired power plant not completed in respect of the Phase 1 Project Facilities with an additional 25 megawatt gas-fired turbine with selective catalyst reduction to meet peak demand requirements, in each case (i) with related onsite utilities and supporting infrastructure and (ii) as such facilities may be improved, replaced, modified, changed or expanded in accordance with the Finance Documents.

Phase 2 LNG Facility Date Certain” means December 31, 2027; provided that if, on or prior to December 31, 2027, the Borrower certifies to the Intercreditor Agent (and the Independent Engineer reasonably concurs with such certification in writing) that (i) the only remaining condition to the Project Phase 2 Completion Date as of the date of delivery of such certification, other than conditions that can only be satisfied on the Project Phase 2 Completion Date, is the condition specified in Section 14.3(c)(iii) (Conditions to Occurrence of the Project Phase 2 Completion Date – Physical Completion Certificate) and (ii) the Lenders’ Reliability Test has commenced in accordance with the procedures specified in Section 12.11 (Witnessing Performance Tests and Lenders’ Reliability Tests; Settlement of Liquidated Damages) and the Independent Engineer reasonably expects the Lenders’ Reliability Test to be completed on or prior to March 30, 2028, then for all purposes under this Agreement the “Phase 2 LNG Facility Date Certain” means March 30, 2028.

Phase 2 LTS Purchase Order” means that certain Purchase Order Contract for the Sale of Liquefaction Train System, dated as of August 5, 2022, by and between the Borrower and BHES, as supplemented by the LNTP, dated as of September 15, 2022 and the FNTP, dated as of December 15, 2022.

Phase 2 Marine Works Construction Agreement” means that certain Construction Agreement relating to Marine Works (Phase 2), dated as of October 10, 2022, by and between the Borrower and Weeks-Massman, as supplemented by Anticipated LNTP, dated as of October 14, 2022.

Phase 2 Material Construction Contracts” means, together, each of the following documents:

 

  (a)

the Phase 2 EPC Contract;

 

  (b)

the Phase 2 LTS Purchase Order;

 

  (c)

the PIS 2022 Purchase Order;

 

  (d)

the Phase 2 Pretreatment Contract;

 

  (e)

the Phase 2 Marine Works Construction Agreement; and

 

-258-

Plaquemines – Amended & Restated Common Terms Agreement


  (f)

the Phase 2 Storage Tanks EPC Contract.

Phase 2 Material Project Agreements” means:

 

  (a)

the Phase 2 Initial LNG SPAs (except the Phase 2 Excess Capacity LNG SPA);

 

  (b)

the Phase 2 Initial LNG SPA Guarantees;

 

  (c)

the Phase 2 Material Construction Contracts;

 

  (d)

the Gas Transportation Agreements;

 

  (e)

the Service Agreements (other than the agreement described in clauses (g), (h) and (i) of the definition thereof);

 

  (f)

from and after the entry into such agreement, the agreement described in clause (g), (h) and (i) of the definition of “Service Agreements”;

 

  (g)

the Leases;

 

  (h)

the Phase 2 Parent Guarantees;

 

  (i)

prior to the Project Phase 2 Completion Date, the Access License Agreements;

 

  (j)

the Pipeline Service Agreements; and

 

  (k)

any Subsequent Material Project Agreement with respect to the Phase 2 LNG Facility,

provided, however, any Phase 2 Material Project Agreement shall cease to be a Phase 2 Material Project Agreement when all material obligations thereunder have been performed and paid in full.

Phase 2 Material Project Counterparties” means each of the Phase 2 Construction Contractors, the Phase 2 Initial LNG Buyers, New Fortress Energy Inc., China Gas Holdings Limited, Excelerate Energy Limited Partnership, Texas Eastern Transmission, LP, Tennessee Gas Pipeline Company, L.L.C., Columbia Gulf Transmission, LLC, Baker Hughes Holdings LLC, General Electric Company, McDermott International, Ltd., Honeywell International Inc., KBR, Inc., Zachry Holdings, Inc., Plaquemines Tug Services, LLC, the Manager, the Operator, the Pipeline Operator, The Plaquemines Port Harbor and Terminal District, Plaquemines Land Ventures, LLC and each other party (other than an Obligor) to a Phase 2 Material Project Agreement.

 

-259-

Plaquemines – Amended & Restated Common Terms Agreement


Phase 2 Parent Guarantees” means:

 

  (a)

Guaranty Agreement, dated as of February 8, 2022, by Baker Hughes Holdings LLC for the benefit of the Borrower, relating to the PIS 2022 Purchase Order;

 

  (b)

Parent Guaranty Agreement, dated as of February 24, 2022, by General Electric Company for the benefit of BHES and the Borrower, as supplemented by Letter Agreement, dated as of February 24, 2022, by and between General Electric Company, BHES and the Borrower, relating to the PIS 2022 Purchase Order;

 

  (c)

Parent Guarantee (Phase 2), dated as of April 12, 2019, by McDermott International, Ltd. (as assignee of McDermott International, Inc.), in favor of the Borrower, pursuant to the Assignment, Assumption, and Amendment Agreement, dated as of November 8, 2021, by and among McDermott International, Inc., McDermott International, Ltd., the Borrower and CB&I;

 

  (d)

Guaranty Agreement, dated as of August 5, 2022, by Baker Hughes Holdings LLC for the benefit of the Borrower, relating to the Phase 2 LTS Purchase Order;

 

  (e)

Parent Guarantee (Phase 2), dated as of April 12, 2019, by Honeywell International Inc. in favor of the Borrower; and

 

  (f)

each Phase 2 EPC Contract Guaranty.

Phase 2 Pre-Completion Revenues Account” is the account described in Section 4.3(a)(iv) (Accounts) of the Common Security and Account Agreement.

Phase 2 Pretreatment Contract” means that certain Amended and Restated Engineering and Procurement Agreement (Phase 2), dated as of August 26, 2022, by and between the Borrower and UOP, as supplemented by the Anticipated LNTP, dated as of August 26, 2022, and Notice to Proceed, dated as of February 22, 2023, together with that certain Amended and Restated Natural Gas Integrated Pretreatment Block License Agreement (Phase 2), dated as of August 26, 2022, by and between the Borrower and UOP.

Phase 2 Storage Tanks EPC Contract” means that certain LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 2), dated as of April 12, 2019, by and between the Borrower and CB&I, as amended by Amendment No. 1 to LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 2), dated as of June 25, 2021, Amendment No. 2 to LNG Storage Tanks Engineering, Procurement and Construction Agreement (Phase 2), dated as of September 29, 2021, Change Order No. 1, dated as of June 6, 2022, Change Order

 

-260-

Plaquemines – Amended & Restated Common Terms Agreement


No. 2, dated as of October 28, 2022, Change Order No. 3, dated as of December 2, 2022 and Change Order No. 4, dated as of January 30, 2023, as supplemented by Notice to Proceed, dated as of March 31, 2022, as assigned from Borrower to Venture Global LNG, Inc. pursuant to that certain Assignment and Assumption Agreement, dated as of March 31, 2022, and as assigned from Venture Global LNG, Inc. to Borrower pursuant to that certain Assignment and Assumption Agreement, dated as of March 13, 2023.

Pipeline Construction Contracts” means:

 

  (a)

the Pipeline Construction Agreement, dated as of August 12, 2021, by and between the Guarantor and Sunland Construction, Inc., as amended by Change Order No. 1 dated as of February 9, 2022, Change Order No. 2, dated as of July 11, 2022, and Change Order No. 3, dated as of February 14, 2023, and as supplemented by Limited Notice to Proceed No. 1, dated as of November 12, 2021, Limited Notice to Proceed No. 2, dated as of November 12, 2021, Extra Work Authorization No. 0001, Rev. 1, dated as of December 2, 2021, Limited Notice to Proceed No. 3, dated as of January 26, 2022, Extra Work Authorization No. 0002, dated as of February 2, 2022, Limited Notice to Proceed No. 4, dated as of April 14, 2022, Limited Notice to Proceed No. 5, dated as of May 3, 2022, Limited Notice to Proceed No. 6, dated as of May 13, 2022 and Full Notice to Proceed, dated as of May 25, 2022 (the “Sunland Pipeline Construction Contract”); and

 

  (b)

the Engineering, Procurement and Construction Management Agreement, dated as of August 25, 2021, by and between the Guarantor and Gulf Interstate Engineering Company, as amended by Amendment No. 1 to Engineering, Procurement and Construction Management Agreement, dated as of March 3, 2023, and as supplemented by Full Notice to Proceed, dated as of October 11, 2021, and as amended by Change Order No. 1, dated as of January 18, 2022, Change Order No. 2, dated as of March 3, 2022, Change Order No. 3, dated as of December 13, 2022, Change Order No. 4, dated as of February 22, 2023 and Amendment No. 1 to Engineering, Procurement and Construction Management Agreement, dated as of March 3, 2023.

Pipeline Contractors” means Sunland Construction, Inc. and Gulf Interstate Engineering Company.

“Pipeline Operator” means Gator Express Operations, LLC, a limited liability company organized under the laws of the State of Delaware.

Pipeline Service Agreements” means:

 

-261-

Plaquemines – Amended & Restated Common Terms Agreement


  (a)

Firm Transportation Service Agreement, dated as of April 18, 2022, by and between the Guarantor and the Borrower;

 

  (b)

Interruptible Transportation Service Agreement, dated as of April 18, 2022, by and between the Guarantor and the Borrower;

 

  (c)

Service Agreement for Rate Schedule FT-1, dated as of January 31, 2021, by and between the Borrower and Texas Eastern Transmission, LP;

 

  (d)

Interconnect Agreement (Gator Express M&R 74530), dated as of August 26, 2020, between the Guarantor and Texas Eastern Transmission, LP, as amended by Amendment to Interconnect Agreement, dated as of April 29, 2022;

 

  (e)

Amended and Restated Interconnect Agreement (Gator Express Meter Fac 4095), dated as of March 31, 2022, between the Guarantor and Tennessee Gas Pipeline Company, L.L.C.;

 

  (f)

FTS-1 Service Agreement, dated as of May 2, 2022, between Columbia Gulf Transmission, LLC and the Borrower;

 

  (g)

Negotiated Rate Letter Agreement, dated as of April 22, 2022, between Columbia Gulf Transmission, LLC and the Borrower;

 

  (h)

Discounted Rate Agreement, dated as of February 14, 2023, between Tennessee Gas Pipeline Company, L.L.C. and the Borrower;

 

  (i)

Gas Transportation Agreement, dated as of February 14, 2023, between Tennessee Gas Pipeline, L.L.C. and the Borrower.

PIS 2021 Purchase Order” means that certain Purchase Order Contract for the Sale of Power Island System, dated as of February 26, 2021, by and between the Borrower and BHES, as amended by Amendment No. 1 to Purchase Order Contract for the Sale of Power Island System, dated as of March 26, 2021, as modified by Change Order No. 01, dated as of September 28, 2021, Change Order No. 02, dated as of April 30, 2022, Change Order No. 03, dated as of December 23, 2022, and Change Order No. 04, dated as of December 23, 2022, and as supplemented by the Full Notice to Proceed Under the Purchase Order Contract for the Sale of Power Island System, dated as of November 18, 2021, issued by the Borrower, the Letter Agreement re: UOP Pre-Treatment System, dated as of December 22, 2021, and the Letter Agreement re: UOP Pre-Treatment System, dated as of May 23, 2022.

PIS 2022 Purchase Order” means that certain Purchase Order Contract for the Sale of Power Island System, dated as of February 3, 2022, by and between the Borrower and BHES, as supplemented by the Full Notice to Proceed Only for Tranche A under the Purchase Order Contract for the Sale of Power Island System,

 

-262-

Plaquemines – Amended & Restated Common Terms Agreement


dated as of February 3, 2022, issued by the Borrower, Letter Agreement re: UOP Pre-Treatment System, dated as of May 23, 2022, the Full Notice to Proceed Only for Tranche B under the Purchase Order Contract for the Sale of Power Island System, dated as of September 30, 2022, issued by the Borrower and Letter Agreement re: UOP Pre-Treatment System, dated as of October 13, 2022 and as modified by the Change Order No. 01, dated December 31, 2022.

Plan” means any “employee benefit plan” as defined in Section 3(3) of ERISA, including any “employee welfare benefit plan” (as defined in Section 3(1) of ERISA) and/or any “employee pension benefit plan” (as defined in Section 3(2) of ERISA), that is or was maintained or contributed to by any Obligor or any ERISA Affiliate.

Plaquemines Holdings” means Plaquemines LNG Holdings, LLC, a Delaware limited liability company.

Pledge Agreement” has the meaning given in Section 3.3 (Security Interests to be Granted by Pledgor) of the Common Security and Account Agreement.

Pledged Collateral” has the meaning given in Section 3.2(a) (Security Interests to be Granted by the Obligors – Pledge of Pledged Collateral) of the Common Security and Account Agreement.

Pledged Debt Securities” has the meaning given in Section 3.2(a)(vii) (Security Interests to be Granted by the Obligors – Pledge of Pledged Collateral) of the Common Security and Account Agreement.

Pledged Equity Interests” has the meaning given in Section 3.2(a)(i) (Security Interests to be Granted by the Obligors – Pledge of Pledged Collateral) of the Common Security and Account Agreement.

“Pledgor” means Plaquemines LNG Pledgor, LLC, a limited liability company organized under the laws of the State of Delaware.

“Pledgor Reaffirmation Agreement” means the Reaffirmation and Acknowledgment Agreement, dated as of the Upsize Closing Date, by and between the Pledgor and the Collateral Agent.

Pre-Completion Quantities” has the meaning given in Section 8.5(a) (Sale of Pre- Completion Quantities).

Pre-Completion Revenues” has the meaning given in Section 8.5(a)(iii) (Sale of Pre-Completion Quantities).

 

-263-

Plaquemines – Amended & Restated Common Terms Agreement


Pro Rata Payment” means, in respect of the Senior Debt Obligations, a payment to a Senior Creditor on any date on which a payment of Senior Debt Obligations is made in which:

 

  (a)

the amount of interest paid to such Senior Creditor on such date bears the same proportion to the total amount of interest payments made to all Senior Creditors on such date as (i) the total amount of Senior Debt Obligations for interest due to such Senior Creditor on such date bears to (ii) the total amount of Senior Debt Obligations for interest due to all Senior Creditors on such date;

 

  (b)

the amount of principal paid to such Senior Creditor on such date bears the same proportion to the total amount of principal payments made to all Senior Creditors on such date as (i) the total amount of Senior Debt Obligations for principal due to such Senior Creditor on such date bears to (ii) the total amount of Senior Debt Obligations for principal due to all Senior Creditors on such date, in each case not including any principal payable by way of an acceleration of principal unless each Senior Debt Obligation has been accelerated; and

 

  (c)

fees, commissions, indemnities and all amounts other than interest and principal paid to such Senior Creditor on such date bears the same proportion to the total fees, commissions, indemnities and such other amounts paid to all Senior Creditors on such date as (i) the total Senior Debt Obligations for fees, commissions, indemnities and such other amounts due to such Senior Creditor on such date bears to (ii) the total Senior Debt Obligations for fees, commissions, indemnities and such other amounts due to all Senior Creditors on such date.

If payments cannot be made exactly in such proportion due to minimum required payment amounts and required integral multiples of payments under Senior Debt Instruments, payments made in amounts as near such exactly proportionate amounts as possible shall be deemed to be Pro Rata Payments.

Project” means the approximately 20.0 MTPA nameplate LNG liquefaction and export project located alongside the Mississippi River in Plaquemines Parish, Louisiana, consisting of the Phase 1 Project Facilities and the Phase 2 LNG Facility.

Project Costs” means all costs of acquiring, leasing, designing, engineering, developing, permitting, insuring, financing (including (a) the repayment in full of the Bridge Loans and any accrued and unpaid interest thereon and (b) closing costs, other fees and expenses, commissions and discounts payable to any purchaser or underwriter of Senior Notes (to the extent such costs are paid from the proceeds of such Senior Notes), insurance costs (including premiums) and, except to the extent paid from the Revenue Account in accordance with Section 4.7(a)(ii) (Cash

 

-264-

Plaquemines – Amended & Restated Common Terms Agreement


Waterfall) or Section 4.7(a)(iii) (Cash Waterfall), interest during construction and interest rate hedge expenses and Secured Party Fees during construction), constructing, installing, commissioning, testing and starting-up (including costs relating to all equipment, materials, spare parts and labor for) the Project Facilities, funding the Senior Facilities Debt Service Reserve Account and the Contingency Reserve Account and all other costs incurred with respect to the Development in accordance with the Construction Budget and Schedule, including working capital prior to the end of the Term Loan Availability Period (on terms set forth for the Working Capital Facility in the Credit Facility Agreement), gas purchase, transport and storage costs and Operation and Maintenance Expenses, in each case incurred, with respect to the Phase 1 Project Facilities, prior to the Project Phase 1 Completion Date and, with respect to the Phase 2 LNG Facility, prior to the Project Phase 2 Completion Date, and/or reimbursement of Drawstop Equity Contributions solely to the extent the proceeds of such Drawstop Equity Contributions have been used to pay Project Costs and after satisfaction of the conditions set forth in Section 4.3 (Conditions to Each Term Loan Advance). On any date on which a determination is being made whether specific sources of funding available to the Obligors are sufficient for the Development to achieve the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain or the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain, the Project Costs against which the applicable sources of funding are measured to make this determination will be the remaining Project Costs required to be spent in order to achieve the Project Phase 1 Completion Date and/or the Project Phase 2 Completion Date as determined as of such determination date based on the then-current Construction Budget and Schedule, including in the case of commissioning costs determined on a net basis consistent with the then-current Construction Budget and Schedule.

Project Facilities” means the Phase 1 Project Facilities and the Phase 2 LNG Facility, as such facilities may be repaired and replaced from time to time or modified, changed or expanded as permitted in the Finance Documents.

Project Phase 1 Completion Date” means the date upon which all of the conditions set forth in Section 14.1 (Conditions to Occurrence of the Project Phase 1 Completion Date) of the Common Terms Agreement have been either satisfied, or, in each case, waived by the Requisite Intercreditor Parties.

Project Phase 1 Development” means the financing, development, engineering, acquisition, ownership, occupation, construction, equipping, testing, commissioning, completing, insurance, repair, operation, maintenance and use of the Phase 1 Project Facilities and the purchase, transportation and sale of Gas and the production, storage and sale of LNG, the export of LNG from the Phase 1 Project Facilities, the transportation of Gas to the Phase 1 Project Facilities by an Obligor or third parties, and the sale of other services or other products or by products of the Phase 1 Project Facilities and all activities incidental thereto, in each case in accordance with the Transaction Documents.

 

-265-

Plaquemines – Amended & Restated Common Terms Agreement


Project Phase 2 Completion Date” means the date upon which all of the conditions set forth in Section 14.3 (Conditions to Occurrence of the Project Phase 2 Completion Date) of the Common Terms Agreement have been either satisfied, or, in each case, waived by the Requisite Intercreditor Parties.

Project Phase 2 Completion Date Distribution” means an amount equal to any amounts remaining on deposit in the Construction Account after giving effect to the application of clauses (iii)(A) through (iii)(E) of Section 14.4(c) (Project Phase 2 Completion Date Waterfall).

Project Phase 2 Development” means the expansion of the Project to develop, engineer, construct and operate the Phase 2 LNG Facility.

Project Property” means, at any point in time, all Project Facilities, material Permits in respect of the Development, information, data, results (technical, economic, business or otherwise) known and other information that was developed or acquired as a result of Development operations.

“Prudent Industry Practice” means, at a particular time, any of the practices, methods, standards and procedures (including those engaged in or approved by a material portion of the LNG industry) that, at that time, in the exercise of reasonable judgment in light of the facts known at the time a decision was made, could reasonably have been expected to accomplish the desired result consistent with good business practices, including due consideration of the Development’s reliability, environmental compliance, economy, safety and expedition, and which practices, methods, standards and acts generally conform to International LNG Terminal Standards and International LNG Vessel Standards, and solely with respect to Section 12.27 (Gas Transportation Arrangements; Gas Purchase Arrangements) of the Common Terms Agreement and the definition of “Qualified Gas Supplier”, the standard industry practice applicable to the gas supply industry, including providing due consideration of the need for reliable supply and taking into account the credit quality, track record and experience of suppliers, diversity of supply sources, quality of gas supplied and prudent contracting strategy in order to enable the Development to receive the quantum of natural gas required from time to time to meet the obligations of the Obligors under the LNG SPAs.

PUHCA” means the Public Utility Holding Company Act of 2005 and FERC’s implementing regulations.

 

-266-

Plaquemines – Amended & Restated Common Terms Agreement


Qualified ECP Party” means, in respect of any Swap Obligation, each Obligor that has total assets exceeding $10 million at the time the relevant guaranty or grant of the relevant security interest becomes effective with respect to such Swap Obligation or such other person as constitutes an “eligible contract participant” under the Commodity Exchange Act or any regulations promulgated thereunder and can cause another person to qualify as an “eligible contract participant” at such time by entering into a keepwell under Section 1a(18)(A)(v)(II) of the Commodity Exchange Act.

Qualified Gas Supplier” means suppliers of Gas reasonably selected from time to time by the Borrower in accordance with Prudent Industry Practice, including the suppliers listed on Exhibit A to the Gas Sourcing Plan, as updated semi-annually.

Qualified Operator” means any Person that, directly or indirectly through an affiliate, within the last five years, (a) is engaged in the business of procuring or transporting at least 1.0 Bcf of natural gas per day, (b) has operated LNG liquefaction facilities processing not less than 4.5 MTPA of LNG and (c) is in compliance with the requirements of the USA Patriot Act (including applicable, and uniformly applied, “know your customer” regulations) and all other applicable Anti-Terrorism and Money Laundering Laws and satisfies applicable “know your customer” requirements of the Facility Lenders. “Qualified Owner” means any Person that, directly or through an affiliate, (a) either (i) is (or is a Subsidiary or a controlled affiliate of) a Qualified Operator, (ii) has engaged a Qualified Operator to operate the Project Facilities, (iii) has engaged with one or more Affiliates of Venture Global LNG, Inc. to operate the Project Facilities or (iv) has provided the Intercreditor Agent with a certificate from the Independent Engineer stating that such Person (or its designated operator) is qualified to operate the Project Facilities, (b) either (i) has an Investment Grade rating or (ii) is a person that has a tangible net worth or assets of at least $10 billion, (c) has satisfied applicable “know your customer” requirements of the Facility Lenders and (d) is in compliance with the requirements of the USA Patriot Act (including applicable, and uniformly applied, “know your customer” regulations) and all other applicable Anti-Terrorism and Money Laundering Laws.

Qualified Transporter” means any Person possessing the requisite FERC permit or requisite Louisiana Public Service Commission authorization to transport Gas.

Qualifying LNG SPA” has the meaning given in Section 8.1(b) (LNG SPA Maintenance) of the Common Terms Agreement.

Qualifying Term” means (a) with respect to any new LNG SPA that meets the conditions to be, or is approved as, a Qualifying LNG SPA, the term of such LNG SPA is no shorter than the lesser of (i) 12 years and (ii) the remaining notional 20- year amortization term of the Upsized Senior Debt or (b) with respect to any LNG SPA replacing a Qualifying LNG SPA, a term at least as long as the remaining term of the Qualifying LNG SPA it is replacing.

 

-267-

Plaquemines – Amended & Restated Common Terms Agreement


Quarterly Payment Date” means each March 31, June 30, September 30 and December 31.

Real Estate” means all land, together with the buildings, structures, parking areas, and other improvements thereon, now or hereafter owned by an Obligor, including all easements, rights-of-way, servitudes and similar rights relating thereto and all leases and tenancies, and all rights of occupancy thereof of a nature comparable to a lease.

Real Property Documents” means, at any time, (i) the documents evidencing the Real Estate owned (or leased) by the Obligors and (ii) the documents evidencing the Real Estate in which a license or servitude has been granted to an Obligor (including, for the avoidance of doubt for purposes of this clause (ii), documents evidencing Real Estate on which the Gator Express Pipeline is or is to be situated). As of the Upsize Closing Date, such documents referenced in clause (i) are set forth on Schedule U (Real Property Documents) to the Common Terms Agreement.

Reasonable Commercial Terms” has the meaning given in Section 12.28(a) (Insurance Covenant) of the Common Terms Agreement.

Receivable” means (i) all Accounts (as defined in the UCC) and (ii) all other rights to payment for goods or other property sold, leased, licensed, assigned or otherwise disposed of or for services rendered or to be rendered, whether or not such right is evidenced by an Instrument or Chattel Paper (each as defined in the UCC) or classified as a General Intangible (as defined in the UCC) and whether or not it has been earned by performance. References herein to Receivables shall include any Supporting Obligation (as defined in the UCC) or collateral securing such Receivable.

Receiver” means an administrator, a receiver or receiver and manager, or, where permitted by law, an administrative receiver or equivalent officer or person in a relevant jurisdiction of the whole or any part of the Collateral.

Register” has the meaning given in Section 19.7 (Register) of the Common Terms Agreement.

Related Parties” means, with respect to any specified Person, such Person’s Affiliates and the respective shareholders, members, partners, directors, officers, employees, agents, trustees, advisors and representatives of such Person and such Person’s Affiliates.

Release” means, with respect to any Hazardous Material, any release, spill, emission, leaking, pouring, emptying, escaping, dumping, pumping, injection, deposit, disposal, discharge, dispersal, leaching or migration of such Hazardous Material into the environment, including the movement of such Hazardous Material through ambient air, soil, surface water, ground water, wetlands, land or subsurface strata.

 

-268-

Plaquemines – Amended & Restated Common Terms Agreement


Relevant Interest Period” means, with respect to each Loan, the “Interest Period” and/or “Interest Payment Period”, as applicable, as defined in the relevant Facility Agreement.

Repeated Representations” means the representations and warranties described in Section 5.2 (Repeated Representations and Warranties of the Obligors) of the Common Terms Agreement.

Replacement Debt” has the meaning given in Section 6.3(a) (Replacement Debt) of the Common Terms Agreement.

Replacement Facility Agent Accession Agreement” has the meaning given in Section 19.3(b)(ii) (Replacement of Facility Agents) of the Common Terms Agreement.

Replacement Material Contract” means any agreement entered into in replacement of a Material Project Agreement (a) which has substantially similar or more favorable economic effect for Borrower or the Guarantor, as applicable, when taken as a whole together with any other agreements related thereto and (b) which has substantially similar or more favorable non-economic terms (taken as a whole) for Borrower or the Guarantor, as applicable, as the Material Project Agreement being replaced.

Required Capital Expenditures” means capital expenditures required to meet the requirements of any applicable laws and regulations, Permits (or interpretations thereof), or insurance policies, Industry Standards, and Prudent Industry Practice with which the Obligors are obligated to comply under any Material Project Agreement and any other material agreements of the Obligors relating to the Development, including those relating to the environment.

Required Export Authorization” means, with respect to a Qualifying LNG SPA at any time, (a) the Non-FTA Authorization and (b) the FTA Authorization to the extent that (i) at such time, the volumes permitted to be exported under the FTA Authorization or the Non-FTA Authorization, as the case may be, are required in order to enable the sale of such Qualifying LNG SPA’s share of the then-applicable Base Committed Quantity of LNG in accordance with the terms of such Qualifying LNG SPA and (ii) an objection has not been received in respect of the identification of such Export Authorization as being (or not being) a “Required Export Authorization” pursuant to Section 8.1(b)(iv) (LNG SPA Maintenance) of the Common Terms Agreement. For the avoidance of doubt, the Non-FTA Authorization is a Required Export Authorization for each of the Initial LNG SPAs (other than the Excess Capacity LNG SPAs) in effect on the Upsize Closing Date and until otherwise determined in accordance with Section 8.2(a)(ii) (LNG SPA Mandatory Prepayment) of the Common Terms Agreement.

 

-269-

Plaquemines – Amended & Restated Common Terms Agreement


Required Intercreditor Parties” has the meaning given in Section 1.1 (Definitions) of the Intercreditor Agreement.

Required LNG SPA” means, at any time, the Qualifying LNG SPAs required to be maintained pursuant to Section 8.1(a) (LNG SPA Covenants – LNG SPA Maintenance) of the Common Terms Agreement at such time.

Requisite Intercreditor Parties” has the meaning given in Section 1.1 (Definitions) of the Intercreditor Agreement.

Reservations” means the principle that equitable remedies are remedies which may be granted or refused at the discretion of the court, the limitation of enforcement by laws relating to bankruptcy, insolvency, liquidation, re- organization, court schemes, moratorium, administration and other laws generally affecting the rights of creditors, the time barring of claims under any legislation relating to limitation of claims, the possibility that an undertaking to assume liability for or to indemnify a Person against non-payment of stamp duty may be void, defenses of set-off or counterclaim and similar principles, in each case both under New York law and the laws of other applicable jurisdictions and such other qualifications as to matters of law as are contained in the legal opinions provided to the Senior Creditors pursuant to Section 4.1 (Conditions to Initial Closing Date and Initial Advance) and Section 4.2 (Conditions to Upsize Closing Date) of the Common Terms Agreement.

Resolution Authority” means an EEA Resolution Authority or, with respect to any UK Financial Institution, a UK Resolution Authority.

Restricted Document” has the meaning given in Section 12.6(c) (Confidentiality) of the Common Security and Account Agreement.

Restricted Operation and Maintenance Expenses” means Operation and Maintenance Expenses that do not constitute capital expenditures other than Required Capital Expenditures and those expenditures essential to construct the Project Facilities or to maintain the Project Facilities’ capacity at, or to prevent a material increase in operating expenses from, the operating levels then in effect.

Restricted Payment” means (a) any dividend or other distribution by the Borrower (in cash, property of the Borrower, securities, obligations, or other property) on, or other dividends or distributions on account of, or the setting apart of money for a sinking or other analogous fund for, or the purchase, redemption, retirement or other acquisition by the Borrower of, any portion of any membership interest in the Borrower and (b) all payments (in cash, property of the Borrower, securities,

 

-270-

Plaquemines – Amended & Restated Common Terms Agreement


obligations, or other property) of principal of, interest on and other amounts with respect to, or other payments on account of, or the setting apart of money for a sinking or other analogous fund for, or the purchase, redemption, retirement or other acquisition by the Borrower of, any Indebtedness owed to Pledgor or any other Person party to a pledge agreement or any Affiliate thereof, including any Subordinated Debt. Restricted Payments shall not include (i) payments under the Service Agreements (which shall be paid in accordance with Section 4.7 (Cash Waterfall) of the Common Security and Account Agreement), (ii) Permitted Payments (which shall be paid in accordance with Sections 4.5(b)(ii)(D) (Deposits and Withdrawals – Phase 1 Pre-Completion Revenues Account), 4.5(c)(ii)(D) (Deposits and Withdrawals – Phase 2 Pre-Completion Revenues Account) and/or 4.7 (Cash Waterfall) of the Common Security and Account Agreement) and (iii) any of the payments in (a) or (b) above (whether in cash, securities, obligations or otherwise) made among any of the Obligors.

Retained Excess Cash Flow” means, as of any date of determination, amounts on deposit in the Excess Equity Proceeds Account that are available to be utilized for the making of a Restricted Payment under Section 11.1 (Conditions to Restricted Payments), Section 11.3 (Project Phase 1 Pre-Completion Revenue Restricted Payments) or Section 11.4 (Project Phase 2 Pre-Completion Revenue Restricted Payments) of the Common Terms Agreement which, instead of being utilized to make a Restricted Payment, are retained by the Borrower and used for other purposes contemplated by the Finance Documents; provided that, in each case, such amounts shall only be included to the extent (a) the conditions to the making of a Restricted Payment have been satisfied under either Section 11.1 (Conditions to Restricted Payments), Section 11.3 (Project Phase 1 Pre-Completion Revenue Restricted Payments) or Section 11.4 (Project Phase 2 Pre-Completion Revenue Restricted Payments) of the Common Terms Agreement, as applicable and (b) as of any date of determination, such funds exceed the amount deposited into the Excess Equity Proceeds Account to fund any then remaining obligations and liabilities in respect of any Expansion and the activities described in sub-clauses (a) through (d) of Section 7.2 (Expansion Contracts).

Revenue Account” is the account described in Section 4.3(a)(vi) (Accounts) of the Common Security and Account Agreement.

Rolling Stock” means any motor vehicles, tractors, trailers and other like property, whether or not the title thereto is governed by a certificate of title or ownership and other rolling stock, including such property for which the title thereto is evidenced by a certificate of title issued by the United States or a state that permits or requires a lien thereon to be evidenced upon such title.

S&P” means Standard & Poor’s Ratings Services, a division of McGraw-Hill Financial, Inc., or any successor thereto.

 

-271-

Plaquemines – Amended & Restated Common Terms Agreement


Sanctioned Person” has the meaning given in Section 5.1(g)(iv) (Sanctions, Anti- Corruption Laws and USA Patriot Act) of the Common Terms Agreement.

Sanctions” means any financial sanctions or economic or trade embargoes administered or enforced from time to time by the U.S. Department of State or the U.S. Department of Treasury (including the Office of Foreign Assets Control), or any other applicable U.S. sanctions authority (including OFAC Laws), the United Nations Security Council, the European Union, any EU member state or His Majesty’s Treasury.

Sanctions Violation” has the meaning given in Section 12.6(d) (Compliance with Law) of the Common Terms Agreement.

Schedule Bonus” means the bonus for completion as described in Section 7 of the Phase 1 EPC Contract and Section 7 of the Phase 2 EPC Contract, the bonus for early completion as described in Section 6.9 of the Sunland Pipeline Construction Contract, the delivery bonus as described in Section 6.7 of Appendix A to the Phase 1 LTS Purchase Order or Section 6.7 of Appendix A to the Phase 2 LTS Purchase Order, the early delivery bonus as described in Section 13.1 of the Phase 1 Pretreatment Contract or Section 13.1 of the Phase 2 Pretreatment Contract, the early completion bonus as described in Section 19.4 of the Construction Dock and Marine Offloading Facilities Construction Agreement, the early completion bonus as described in Section 19.2 of the Phase 1 Marine Works Construction Agreement, the early completion bonus as described in Section 6.10 of the Storm Surge Wall Construction Agreement, and the delivery bonus as described in Section 6.7 of the PIS 2021 Purchase Order, as applicable.

Schedule of Minimum Insurance” has the meaning given in Section 12.28(a) (Insurance Covenant) of the Common Terms Agreement.

Secured Accounts” means the Accounts, excluding the Excluded Unsecured Accounts.

Secured Parties” means the Senior Creditors, the Senior Creditor Group Representatives, the Intercreditor Agent, the Collateral Agent and the Account Bank.

Secured Party Fees” means any fees, costs, indemnities, charges, disbursements, liabilities and expenses (including reasonably incurred legal fees and expenses) and all other amounts payable to the Collateral Agent, the Intercreditor Agent, the Indenture Trustee or the Account Bank, as applicable, or any of their respective agents and to any Senior Creditor Group Representative.

Securities Act” means the Securities Act of 1933.

 

-272-

Plaquemines – Amended & Restated Common Terms Agreement


Security Documents” means the Common Security and Account Agreement and any other document, agreement, notice, mortgage, instrument or filing creating and/or perfecting any Lien required to be created or perfected by the Common Security and Account Agreement or any other Finance Document and shall include the Pledge Agreement, the Pledgor Reaffirmation Agreement, any deed of trust or mortgage entered into pursuant to Section 3.2(e) (Security Interests to be Granted by the Obligors – Real Property) of the Common Security and Account Agreement, including the Mortgage, any Patent or Trademark security agreement entered into pursuant to Section 3.5(f) (Perfection and Maintenance of Security Interest – Intellectual Property Recording Requirements) of the Common Security and Account Agreement, and any account control agreement (including the Control Agreements) entered into pursuant to Section 4.12(a) (Local Accounts) of the Common Security and Account Agreement.

Security Enforcement Action” means the exercise by the Collateral Agent (or at its direction), following initiation of enforcement action in compliance with Section 6.2 (Initiation of Security Enforcement Action) and Section 6.3 (Conduct of Security Enforcement Action) of the Common Security and Account Agreement, of enforcement rights with respect to the Collateral and any of the other enforcement rights (including exercising step-in and other rights with respect to the Direct Agreements entered into pursuant to Section 3.4 (Direct Agreements) of the Common Security and Account Agreement) contemplated by the Common Security and Account Agreement, the other Security Documents and the Direct Agreements. For the avoidance of doubt, Security Enforcement Action shall not include any action taken by the Collateral Agent (or at its direction) in accordance with Section 6.1 (Collateral Agent Action Generally) of the Common Security and Account Agreement.

Security Enforcement Action Initiation Request” has the meaning given in Section 6.2(a) (Initiation of Security Enforcement Action) of the Common Security and Account Agreement.

Security Enforcement Action Representative” means, at any time, a Senior Creditor Group Representative, or a group of Senior Creditor Group Representatives acting together, that represents a Majority in Interest of the Senior Creditors (for purposes of this definition only, the “Majority Representative”); provided that:

 

  (a)

for so long as at least 20% of the outstanding principal amount of the Senior Debt Obligations is held by Facility Lenders, the Security Enforcement Action Representative shall be a Senior Creditor Group Representative, or a group of Senior Creditor Group Representatives acting together, that represents a Majority in Interest of the Senior Creditors which includes Facility Lenders holding a majority of the outstanding principal amount of the Senior Debt Obligations held by Facility Lenders;

 

-273-

Plaquemines – Amended & Restated Common Terms Agreement


  (b)

if there is no principal amount of Senior Debt Obligations then outstanding and at least 20% of the aggregate Senior Debt Commitments are held by Facility Lenders, the Security Enforcement Action Representative shall be a Senior Creditor Group Representative, or a group of Senior Creditor Group Representatives acting together, that represents a Majority in Interest of the Senior Creditors which includes Facility Lenders holding a majority of the aggregate Senior Debt Commitments held by Facility Lenders; and

 

  (c)

the Initiating Percentage shall be deemed to be the Security Enforcement Action Representative if and only for so long as the Majority Representative (or the Security Enforcement Action Representative as determined pursuant to clause (a) or (b) above) is not diligently pursuing a Security Enforcement Action unless stayed or otherwise precluded from doing so by law, regulation or order, in which case the Majority Representative (or the Security Enforcement Action Representative as determined pursuant to clause (a) or (b) above) shall remain the Security Enforcement Action Representative until the Majority Representative (or the Security Enforcement Action Representative as determined pursuant to clause (a) or (b) above) is no longer stayed or otherwise precluded from diligently pursuing a Security Enforcement Action and is nonetheless not diligently pursuing such Security Enforcement Action.

Security Interests” means the Liens created or purported to be created by or pursuant to the Security Documents.

Senior Creditor” means a provider of Senior Debt that benefits from the Common Security and Account Agreement, including the Facility Lenders, any Senior Noteholders and each Hedging Bank that is party to, or accedes to, the Common Security and Account Agreement.

Senior Creditor Group” means, at any one time, the following, each of which will constitute a separate Senior Creditor Group:

 

  (a)

the Credit Facility Lender Parties under the Credit Facility Agreement;

 

  (b)

the Facility Lenders (collectively) under any subsequent Facility Agreement;

 

  (c)

the Senior Noteholders (collectively) under any Indenture;

 

  (d)

each Hedging Bank; and

 

  (e)

any Senior Creditor or group of Senior Creditors, as the case may be, that provides Additional Senior Debt pursuant to a single Senior Debt Instrument entered into after the date of the Common Security and Account Agreement.

 

-274-

Plaquemines – Amended & Restated Common Terms Agreement


Senior Creditor Group Representative” means, with respect to any Senior Creditor Group, the representative of such Senior Creditor Group or the incumbent replacement thereof duly appointed as provided in Section 2.4 (Senior Creditor Group Representatives; Replacement or Appointment of Senior Creditor Group Representative) of the Common Security and Account Agreement; provided that, in the case of Hedging Banks acting in the capacity as a Senior Creditor Group Representative, such Hedging Bank shall only be entitled to act in such capacity in accordance with Section 7.3 (Hedging Banks) of the Common Security and Account Agreement. Each Facility Agent shall at all times be the Senior Creditor Group Representative for the relevant Senior Creditor Group and each Indenture Trustee shall at all times be the Senior Creditor Group Representative for the relevant Senior Noteholders.

Senior Debt” means the Upsized Senior Debt, the Working Capital Debt and Senior Notes under the applicable Senior Debt Instrument existing on the Upsize Closing Date, any other permitted Additional Senior Debt (including such as may be incurred under any Senior Notes, or any other Senior Debt Instrument), obligations arising under the Permitted Senior Debt Hedging Instruments, any Permitted Additional Working Capital Debt, and any Replacement Debt, in each case benefiting from the Security Interests created under and pursuant to the Common Security and Account Agreement and incurred from time to time as permitted by the Finance Documents.

Senior Debt Commitments” means the aggregate principal amount any Senior Creditor is committed to disburse to the Borrower under any Senior Debt Instrument.

Senior Debt/Equity Ratio” means, as of the date of measurement, the ratio of (a) the sum of principal amounts of Senior Debt (excluding any Letters of Credit and unfunded Senior Debt Commitments, but including any Working Capital Loans and any LC Reimbursement Payments) incurred as of such date or Senior Debt or Senior Debt Commitments projected to be incurred and funded under the Base Case Forecast as of such date, as applicable, to (b) the aggregate amount of Equity Funding (other than Equity Funding as described in clause (f) of the definition thereof) applied as of such date towards Project Costs or contributed to the Borrower or the Guarantor and on deposit in a Secured Account (including any Cash Flow from operations prior to the Project Phase 2 Completion Date applied towards Project Costs) or Cash Flow from operations projected as of such date to be applied towards Project Costs under the Base Case Forecast (including Equity Funding (other than Equity Funding as described in clause (f) of the definition thereof) constituting Cash Flow that is reasonably expected to be received by the Obligors on or prior to the Project Phase 2 Completion Date), as applicable.

 

-275-

Plaquemines – Amended & Restated Common Terms Agreement


Senior Debt Hedging Termination Amount” means any Permitted Senior Debt Hedging Liability due as a result of the termination of a Permitted Senior Debt Hedging Instrument and/or the termination of any transaction entered into thereunder.

Senior Debt Instrument” means:

 

  (a)

each Facility Agreement, including with respect to each Facility Agreement, the Common Terms Agreement;

 

  (b)

any Indenture and any Senior Notes issued pursuant to such Indenture; and

 

  (c)

any credit agreement, indenture, trust deed, note or other instrument pursuant to which the Borrower incurs permitted Additional Senior Debt from time to time.

For the avoidance of doubt, the term “Senior Debt Instrument” shall not include any Permitted Hedging Instrument (including, for the avoidance of doubt, any Permitted Senior Debt Hedging Instrument).

Senior Debt Obligations” means the obligations of the Borrower and the obligations of the Guarantor under its guarantee granted under and pursuant to the Common Security and Account Agreement in each case to pay:

 

  (a)

all principal, interest and premiums on the disbursed Senior Debt;

 

  (b)

all commissions, fees, reimbursements, indemnities, prepayment premiums and other amounts payable to Senior Creditors under any Senior Debt Instrument;

 

  (c)

all Permitted Senior Debt Hedging Liabilities under Permitted Hedging Instruments in respect of which the Hedging Bank has acceded to the Common Security and Account Agreement; and

 

  (d)

all Secured Party Fees;

in each case whether such obligations are present, future, actual or contingent and including the payment of amounts that would become due under the Senior Debt Instruments or the Permitted Senior Debt Hedging Instruments but for the operation of the automatic stay under Section 362(a) of the Bankruptcy Code.

Senior Facilities Debt Service Reserve Account” is the account described in Section 4.3(a)(viii) (Accounts) of the Common Security and Account Agreement.

 

-276-

Plaquemines – Amended & Restated Common Terms Agreement


Senior Facilities Reserve Amount” means as of any date (a) on and after the Project Phase 1 Completion Date, an amount necessary to pay Facility Debt Obligations projected to be due and payable on the next two (in the case of quarterly Payment Dates) or one (in the case of semi-annual Payment Dates) Payment Dates (assuming that no Event of Default will occur during such period) taking into account, with respect to interest, the amount of interest that would accrue on the aggregate principal amount of the Initial Term Loan Amount (as defined in the Credit Facility Agreement) outstanding for the covered six month period and only such interest amount after giving effect to any Permitted Hedging Instrument in respect of interest rates then in effect and (b) on and after the Project Phase 2 Completion Date, an amount necessary to pay Facility Debt Obligations projected to be due and payable on the next two (in the case of quarterly Payment Dates) or one (in the case of semi-annual Payment Dates) Payment Dates (assuming that no Event of Default will occur during such period) taking into account, with respect to interest, the amount of interest that would accrue on the aggregate principal amount of the Facility Debt Obligations outstanding for the covered six month period and only such interest amount after giving effect to any Permitted Hedging Instrument in respect of interest rates then in effect; provided that (a) the Facility Debt Obligations projected to be due and payable for purposes of this calculation shall not include (i) Working Capital Debt; (ii) any voluntary or mandatory prepayment; or (iii) Hedging Termination Amounts; and (b) for purposes of the calculation of the scheduled principal payments in respect of any Senior Debt, any final balloon payment in respect of such Senior Debt shall not be taken into account and instead only the equivalent of the principal payment on the immediately preceding Payment Date for payment of principal prior to such balloon payment shall be taken into account.

Senior Note Disbursement Accounts” has the meaning given in Section 4.3(a)(ii) (Accounts) of the Common Security and Account Agreement.

“Senior Noteholder” means any holder of Senior Notes (or lenders in the case of a “term loan B” financing that the Borrower has elected to be treated as an Indenture).

Senior Notes” means the notes to be issued (or facility agreement to be entered into in the case of a “term loan B” financing that the Borrower has elected to be treated as an Indenture) pursuant to any Indenture.

Service Agreements” means:

 

  (a)

the Amended and Restated Operation and Maintenance Agreement, dated as of March 13, 2023, by and between the Borrower and the Operator;

 

  (b)

the Administrative Services Agreement, dated as of April 19, 2022, by and between the Borrower and the Manager;

 

  (c)

the Pipeline Operation and Maintenance Agreement, dated as of April 19, 2022, by and between the Guarantor and the Pipeline Operator;

 

-277-

Plaquemines – Amended & Restated Common Terms Agreement


  (d)

the Administrative Services Agreement, dated as of April 19, 2022, by and between the Guarantor and the Manager;

 

  (e)

the Field Services Agreement, dated as of May 2, 2022, between the Borrower and BHES, as amended by that certain Amendment No. 1 to Field Services Agreement, dated as of February 27, 2023;

 

  (f)

the Technical Advisor Services Agreement, dated as of April 6, 2022, between the Borrower and UOP, as amended by that certain Amendment No. 1 to Technical Advisor Services Agreement, dated as of March 6, 2023;

 

  (g)

the Agreement for Tug Services, dated as of October 4, 2022, by and between the Borrower and Plaquemines Tug Services, LLC;

 

  (h)

the Shipping Agency Agreement to be entered into by and between the Borrower and Venture Global Commodities, LLC; and

 

  (i)

the long-term service agreement to be entered into by and between the Borrower and BHES.

“Shell” means Shell NA LNG LLC.

SIGTTO” has the meaning given in this Section 1.3 of Schedule A (Common Definitions and Rules of InterpretationDefinitions) within the definition of International LNG Terminal Standards.

“Sinopec” means China Petroleum & Chemical Corp.

“Site” means, collectively, each parcel or tract of land upon which any portion of the Project Facilities are or will be located.

Site Works Contracts” means:

 

  (a)

the Agent for Contract (Agreement Terms), dated as of December 10, 2021, by and between the Borrower and WT Byler Co., Inc., as supplemented by Limited Notice to Proceed No. 1, dated as of December 15, 2021, Limited Notice to Proceed No. 2, dated as of January 3, 2022, as amended by Amended Limited Notice to Proceed No. 2, effective as of January 12, 2022, Amended and Extended Limited Notice to Proceed No. 2, effective as of March 30, 2022 and Amended and Extended Limited Notice to Proceed No. 2, effective as of April 30, 2022;

 

  (b)

the Agent for Contract (Agreement Terms), dated as of December 9, 2021, by and between the Borrower and Remedial Construction Services, L.P., as supplemented by Limited Notice to Proceed No. 1, dated as of December 16, 2021, Limited Notice to Proceed No. 2, Rev 1, dated as of January 6, 2022, Amended Limited Notice to Proceed No. 2, Rev 1, dated as of February 9, 2022, Amended Limited Notice to Proceed No. 2, Rev 2, effective as of March 31, 2022 and Amended Limited Notice to Proceed No. 2, Rev 3, effective as of April 30, 2022;

 

-278-

Plaquemines – Amended & Restated Common Terms Agreement


  (c)

the Agent for Contract, dated as of November 11, 2021, by and between the Borrower and ENTACT Environmental Services, Inc., as supplemented by Limited Notice to Proceed No. 1, dated as of November 23, 2021, Limited Notice to Proceed No. 1A, dated as of December 16, 2021 and Limited Notice to Proceed No. 2, dated as of January 3, 2022, as amended by Amended Limited Notice to Proceed No. 2, effective as of January 12, 2022, Amended and Extended Limited Notice to Proceed No. 2, effective as of March 30, 2022 and Amended and Extended Limited Notice to Proceed No. 2, effective as of April 30, 2022 and Change Order No. 0001, dated as of April 20, 2022, Change Order No. 0002, dated as of April 20, 2022 and Change Order No. 0003, dated as of April 20, 2022;

 

  (d)

Agent for Contract (Agreement Terms), dated as of May 12, 2022, by and between the Borrower and State Service Co., Inc. as supplemented by Notice to Proceed, dated as of May 13, 2022; and

 

  (e)

Agent for Contract (Agreement Terms), dated as of May 12, 2022, by and between the Borrower and Berry Contracting, L.P. dba Bay Ltd. as supplemented by Notice to Proceed, dated as of May 13, 2022.

SOFR” has the meaning given in the Credit Facility Agreement.

Solvent” means, with respect to any Person as of the date of any determination, that on such date:

 

  (a)

the fair valuation of the assets of such Person, on a consolidated basis, is greater than the liabilities of such Person on a consolidated basis, including, without limitation, contingent liabilities;

 

  (b)

the present fair saleable value of the assets of such Person, on a consolidated basis, is at least the amount that will be required to pay the probable liability, on a consolidated basis, of such Person on its debts as they become absolute and matured;

 

  (c)

such Person is able to pay its debts and other liabilities, contingent obligations, and other commitments as they become absolute and matured in the normal course of business; and

 

  (d)

such Person is not engaged in business or a transaction, and is not about to engage in business or a transaction, for which such Person’s assets would constitute unreasonably small capital after giving due consideration to current and anticipated future business conduct.

 

-279-

Plaquemines – Amended & Restated Common Terms Agreement


In computing the amount of contingent liabilities at any time, such liabilities shall be computed at the amount which, in light of the facts and circumstances existing at such time, represents the amount that can reasonably be expected to become an actual or matured liability.

Specified Counterparty” means (a) prior to the Project Phase 1 Completion Date, each of the EPC Contractor, BHES, UOP, collectively, Weeks Marine Inc., and Massman Construction Co., CB&I, and each guarantor party to a Phase 1 Parent Guarantee, (b) prior to the Project Phase 2 Completion Date, each of the EPC Contractor, BHES, UOP, collectively, Weeks Marine Inc., and Massman Construction Co., CB&I, and each guarantor party to a Phase 2 Parent Guarantee,

(c) any counterparty to a Required LNG SPA and (d) any guarantor party to an Initial LNG SPA Guarantee or any other guarantee delivered in respect of a Required LNG SPA.

Sponsor” means Venture Global LNG, Inc., a corporation organized under the laws of the State of Delaware.

Sponsor Intercompany Loan” means that certain Intercompany Loan Agreement, dated as of July 26, 2021, between the Borrower and the Sponsor.

State of Delaware,” “Delaware” or “DE” means the State of Delaware in the United States.

State of New York,” “New York” or “NY” means the State of New York in the United States.

Storm Surge Wall Construction Agreement” means that certain Construction Agreement relating to a Storm Surge Wall, dated as of August 19, 2020, by and between the Borrower and Weeks-Massman, as amended by Amendment No. 1 to Construction Agreement (Storm Surge Wall), dated as of July 1, 2021, Amendment No. 2 to Construction Agreement (Storm Surge Wall), dated as of July 8, 2021, Amendment No. 3 to Construction Agreement (Storm Surge Wall), dated as of October 8, 2021, Amendment No. 4 to Construction Agreement (Storm Surge Wall), dated as of July 14, 2022, Amendment No. 5 to Construction Agreement (Storm Surge Wall), dated as of August 5, 2022, Change Order No. 1, dated as of July 28, 2021, and Change Order No. 2, dated as of September 10, 2021, Change Order No. 3, dated as of May 12, 2022, Change Order No. 4, dated as of August 5, 2022, Change Order No. 5, dated as of August 12, 2022, and as supplemented by Anticipated LNTP, dated as of September 24, 2020, issued by the Borrower, Limited Notice to Proceed No. 2 (Storm Surge Wall), dated as of July 8, 2021, by and among the Borrower and Weeks-Massman, Notice to Proceed, dated as of November 5, 2021, issued by the Borrower.

 

-280-

Plaquemines – Amended & Restated Common Terms Agreement


Subordinated Debt” means any unsecured debt or obligation that ranks subordinate in right of payment to the Senior Debt Obligations, on the basis set forth in a subordination agreement in the form set forth in Schedule S – 1 (Form of General Subordination Agreement) or Schedule S – 2 (Form of Obligor Subordination Agreement) to the Common Terms Agreement, as the case may be.

Subsequent Material Project Agreements” means any contract, agreement, letter agreement or other instrument (other than a Real Property Document) to which an Obligor becomes a party after the Initial Closing Date that:

 

  (a)

replaces or substitutes for an existing Material Project Agreement (including a Replacement Material Contract);

 

  (b)

with respect to any Gas supply contract between any Obligor and any Gas supplier or any Gas transportation contract between any Obligor and any Qualified Transporter, (i) contains obligations and liabilities that are in excess of $75 million per year and (ii) is for a term that is greater than seven years;

 

  (c)

with respect to any contract for the delivery and sale of LNG between any Obligor and any LNG Buyer, (i) contains obligations and liabilities that are in excess of $150 million per year and (ii) is for a term that is greater than seven years; provided that no LNG SPA that is not a Qualifying LNG SPA (or any guarantee thereof) shall constitute a Subsequent Material Project Agreement;

 

  (d)

except as provided in clauses (b) and (c) above, contains obligations and liabilities equal to or in excess of $75 million per year and a committed term of at least five years, with respect to any other contract;

 

  (e)

is a guarantee provided in favor of any Obligor by a guarantor or a counterparty under a Subsequent Material Project Agreement; or

 

  (f)

replaces or substitutes any existing agreement described in clauses (a) through (e) above.

For the purposes of this definition, any series of related transactions shall be considered as one transaction, and all contracts, agreements, letter agreements or other instruments in respect of such transactions shall be considered as one contract, agreement, letter agreement or other instrument, as applicable. Subsequent Material Project Agreements that are executed in a form previously attached to a Material Project Agreement (or Subsequent Material Project Agreement approved by the

 

-281-

Plaquemines – Amended & Restated Common Terms Agreement


Intercreditor Agent (acting at the direction of the Requisite Intercreditor Parties)) will not be subject to the prior Intercreditor Agent approval requirements set forth in Section 12.5 (Material Project Agreements) of the Common Terms Agreement; provided that, the notice requirements in Section 10.3(o) and 10.3(p) (Notices) shall apply to such Subsequent Material Project Agreements.

“Subsidiary means, for any Person, any corporation, partnership, joint venture, limited liability company or other entity of which at least a majority of the securities or other ownership interests having by their terms ordinary voting power to elect a majority of the board of directors or other Persons performing similar functions of such corporation, partnership or other entity (irrespective of whether or not at the time securities or other ownership interests of any other class or classes of such corporation, partnership or other entity shall have or might have voting power by reason of the happening of any contingency) is at the time directly or indirectly owned or Controlled by such Person or one or more Subsidiaries of such Person or by such Person and one or more Subsidiaries of such Person and “Subsidiaries” shall have a corresponding meaning.

“Super-Majority Facility Lenders” means Facility Lenders whose share in the outstanding principal amount of the Senior Debt Obligations and whose undrawn Senior Debt Commitments are more than 66.7% of all of the outstanding principal amount of the Senior Debt Obligations and all the undrawn Senior Debt Commitments of all the Facility Lenders.

“Supplemental Phase 1 LNG SPA means the LNG Sales and Purchaser Agreement, dated as of December 26, 2022, between the Borrower and Inpex Energy Trading Singapore Pte. Ltd.

“Supplemental Quantity means the positive difference between (A) 20.0 MTPA of LNG and (B) the then applicable Base Committed Quantity.

“Survey means an American Land Title Association (“ALTA”) survey of the LNG Facility Site, dated not more than 30 days prior to the Initial Closing Date and certified to Borrower, the Intercreditor Agent and the Title Company, showing a state of facts reasonably acceptable to the Intercreditor Agent (including, without limitation, (i) the location of the LNG Facility Site, (ii) all easements benefiting the LNG Facility Site (or constituting a portion of the LNG Facility Site), all easements affecting the LNG Facility Site and all rights of way and existing utility lines referred to in the Title Policy or disclosed by a physical inspection of the LNG Facility Site, (iii) any established building lines, whether by zoning or agreement, and areas affected by restrictive covenants affecting the LNG Facility Site, (iv) adequate access to the portion of the LNG Facility Site comprising the Project Facilities, (v) encroachments, if any, and the extent thereof in feet and inches upon the LNG Facility Site and onto property adjacent to the LNG Facility Site, and (vi) any improvements, whether existing or to the extent constructed, and the

 

-282-

Plaquemines – Amended & Restated Common Terms Agreement


relationship of such improvements by distances to the perimeter of the LNG Facility Site, established building lines and street lines), prepared by an independent surveyor licensed in the State of Louisiana in compliance with the 2016 ALTA/NSPS Minimum Standard Detail Requirements for ALTA/NSPS Surveys, satisfying those “Table A” standards reasonably required by the Collateral Agent, and otherwise sufficient for the Title Company to eliminate the standard survey exception from the Title Policy and to issue the endorsements set forth on Schedule AA (Survey Endorsements).

“Swap Obligation” means any obligation to pay or perform under any agreement, contract or transaction that constitutes a “swap” within the meaning of Section 1a(47) of the Commodity Exchange Act or the regulations thereunder.

“Swing Swap” means an contract which entitles the buyer of the contract to pay a fixed price for natural gas and the seller to pay the gas daily average at a defined location for a defined period of time. The Swing Swap is settled financially, via exchange of cash payment each day as the gas daily average is settled, rather than physically.

“Taxes” means all present or future taxes, levies, imposts, duties, deductions, withholdings (including backup withholding), assessments, fees or other charges, including any interest, additions to tax or penalties applicable thereto, imposed by any Governmental Authority or the government of any foreign jurisdiction, or of any political subdivision thereof, including any and all agencies, branches, departments and administrative and other subdivisions thereof, and any payments in lieu of the foregoing.

“TBtu means one trillion Btus.

Term Loan Availability Period” has the meaning given to it in the Credit Facility Agreement.

Term Loan Commitment” has the meaning given in Exhibit A (Definitions) to the Credit Facility Agreement.

“Term Loans has the meaning given in the Credit Facility Agreement.

Third Party Account Bank” has the meaning given in Section 4.11(a) (Third Party Investment Account) of the Common Security and Account Agreement.

Third Party Investment Account” has the meaning given in Section 4.11(a) (Third Party Investment Account) of the Common Security and Account Agreement.

“Title Company means Fidelity National Title Insurance Company, First American Title Insurance Company and Old Republic National Title Insurance Company.

 

-283-

Plaquemines – Amended & Restated Common Terms Agreement


“Title Policy means one or more fully paid ALTA Loan Policies of Title Insurance (Form 2006) of title insurance as adopted for use in the State of Louisiana, or a pro forma policy prepared prior to payment for, issuance and delivery of the policy, with completed Schedules A and B, showing the proposed insured, the amount of insurance, the exceptions that are proposed to be placed in the final policies to be issued, and the name of the title insurance company and title insurance agent, including all amendments and endorsements thereto, issued by the Title Company in favor of the Collateral Agent, with such coinsurers or reinsurers as may be reasonably required by the Collateral Agent, with such policies:

 

  (a)

in the case of the Title Policy delivered in connection with the Initial Closing Date, in an amount equal to $5,220,014,842.00;

 

  (b)

in the case of a Title Policy obtained in connection with an acquisition of Real Estate after the Initial Closing Date, to the extent that the Obligors are required to obtain such policy in respect of such Real Estate acquisition pursuant to the Common Terms Agreement or Common Security and Account Agreement, then:

(x) in the case such acquisition of Real Estate is for purposes of an Expansion or Development Expenditure to be funded by Loans incurred by the Obligors, the Obligors shall either amend the then-existing Title Policy, replace the then-existing Title Policy with a new Title Policy or, to the extent a tie-in endorsement to the then existing Title Policy obtained in connection with incurrence of Loans is available and obtained, obtain a separate incremental Title Policy covering the acquired Real Estate; and

(y) in the case of an acquisition of any Real Estate by the Obligors other than in the circumstances described in clause (x) above, the Obligors may (but shall not be required to) amend the then-existing Title Policy or replace the then-existing Title Policy with a new Title Policy in an amount consistent with the terms in clause (x) above or shall obtain a Title Policy covering only such acquired Real Estate in an amount not less than the market value, as reasonably determined by the Borrower, of such acquired Real Estate;

in each case with respect to such acquired Real Estate, and in form or forms satisfactory to the Collateral Agent in all respects, with such policies when taken together insuring as of the date of the recording of the applicable mortgage required under Section 3.2(e) (Security Interests to be Granted by the Obligors – Real Property) of the Common Security and Account Agreement creating a Lien on the estates and interests in the Real Estate comprising the LNG Facility, that such mortgage is a first and prior Lien on the estates and interests in the real property comprising the LNG Facility (to the extent the mortgage property consists of interests insurable under the terms of such form of title policy) free and clear of all Liens on and defects of title other than Permitted Liens, and containing or providing for, among other items:

 

-284-

Plaquemines – Amended & Restated Common Terms Agreement


  (a)

no survey exceptions other than those approved by the Collateral Agent; and

 

  (b)

such other endorsements and affirmative assurances (including, to the extent available on commercially reasonable terms, materialmen’s and mechanic’s lien coverage) as the Collateral Agent shall reasonably require and which the title insurers are permitted and willing to issue pursuant to applicable Louisiana Government Rules.

Trade Secret Licenses” means any and all agreements providing for the granting of any right in or to Trade Secrets (whether an Obligor is licensee or licensor thereunder) or otherwise providing for a covenant not to sue for misappropriation or other violation of a Trade Secret.

Trade Secrets” means all trade secrets and all other confidential or proprietary information and know-how, manufacturing and production processes and techniques, inventions, research and development information, technical data, financial, marketing and business data, pricing and cost information, business and marketing plans, and customer and supplier lists and information whether or not the foregoing has been reduced to a writing or other tangible form, including all documents and things embodying, incorporating, or referring in any way to the foregoing, and with respect to any and all of the foregoing:

 

  (a)

all rights to sue or otherwise recover for any past, present and future misappropriation or other violation thereof;

 

  (b)

all proceeds of the foregoing, including license fees, royalties, income, payments, claims, damages, and proceeds of suit now or hereafter due and/or payable with respect thereto; and

 

  (c)

all other rights of any kind accruing thereunder or pertaining thereto throughout the world.

Trademark Licenses” means any and all agreements, licenses and covenants providing for the granting of any right in or to any Trademark or otherwise providing for a covenant not to sue for infringement, dilution or other violation of any Trademark or permitting coexistence with respect to a Trademark (whether an Obligor is licensee or licensor thereunder).

 

-285-

Plaquemines – Amended & Restated Common Terms Agreement


Trademarks” means all United States, foreign and multinational trademarks, trade names, trade styles, trade dress, corporate names, company names, business names, fictitious business names, Internet domain names, service marks, certification marks, collective marks, logos, other source or business identifiers, designs and general intangibles of a like nature, whether or not registered, and with respect to any and all of the foregoing:

 

  (a)

all registrations and applications therefor including the registrations and applications required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Trademarks” (as such schedule may be amended from time to time);

 

  (b)

all extensions and renewals of any of the foregoing and amendments thereto;

 

  (c)

all of the goodwill of the business connected with the use of and symbolized by any of the foregoing;

 

  (d)

all rights to sue or otherwise recover for any past, present and future infringement, dilution or other violation of any of the foregoing or for any injury to the related goodwill;

 

  (e)

all proceeds of the foregoing, including license fees, royalties, income, payments, claims, damages, and proceeds of suit now or hereafter due and/or payable with respect thereto; and

 

  (f)

all other rights of any kind accruing thereunder or pertaining thereto throughout the world.

Transaction Documents” means, collectively, the Finance Documents and the Material Project Agreements.

Transfers” has the meaning given in the relevant Facility Agreement.

UCC” means the Uniform Commercial Code (or any similar or equivalent legislation) as in effect from time to time in any applicable jurisdiction.

UK Financial Institution” means any BRRD Undertaking (as such term is defined under the PRA Rulebook (as amended from time to time) promulgated by the United Kingdom Prudential Regulation Authority) or any person falling within IFPRU 11.6 of the FCA Handbook (as amended from time to time) promulgated by the United Kingdom Financial Conduct Authority, which includes certain credit institutions and investment firms, and certain affiliates of such credit institutions or investment firms.

UK Resolution Authority” means the Bank of England or any other public administrative authority having responsibility for the resolution of any UK Financial Institution.

 

-286-

Plaquemines – Amended & Restated Common Terms Agreement


United States” or “US” means the United States of America.

Unmatured Event of Default” means an Unmatured Loan Facility Event of Default, Unmatured Indenture Event of Default or a comparable unmatured event of default under any other Senior Debt Instrument entered into after the date of the Common Security and Account Agreement.

Unmatured Indenture Event of Default” means an event that, with the giving of notice, lapse of time or making of a determination, would constitute an Indenture Event of Default.

Unmatured LNG SPA Prepayment Event” means an event that, with the giving of notice or lapse of a cure period, would become an LNG SPA Prepayment Event.

Unmatured Loan Facility Event of Default” means a misrepresentation, breach of undertaking or other event or condition that has occurred and that, with the giving of notice or lapse of time or making of a determination, would constitute a Loan Facility Event of Default.

UOP” means UOP LLC.

Upsize Closing” means the satisfaction or waiver of all the conditions precedent set forth in Section 4.2 (Conditions to Upsize Closing Date) of the Common Terms Agreement, with respect to the Incremental Senior Debt.

Upsize Closing Conditions Certificate” has the meaning given in Section 4.5(b) (Satisfaction of Conditions) of the Common Terms Agreement.

Upsize Closing Date” means the date on which the conditions precedent set forth in Section 4.2 (Conditions to Upsize Closing Date) of the Common Terms Agreement have been satisfied or waived. For the avoidance of doubt, the Upsize Closing Date is March 13, 2023.

Upsize Closing Date DSCR” means 1.45:1.

Upsize Closing Notice” has the meaning given in Section 4.5(b) (Satisfaction of Conditions) of the Common Terms Agreement.

Upsize Commitment Letter” means that certain Commitment Letter, dated as of March 13, 2023, by and among, the Obligors and the Banks (as defined therein) party thereto.

Upsize Permitted Senior Debt Hedging Instrument” means each Permitted Senior Debt Hedging Instrument identified as such in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement as of the Upsize Closing Date.

 

-287-

Plaquemines – Amended & Restated Common Terms Agreement


Upsize Senior Creditor” means each Senior Creditor under an Upsized Senior Debt Instrument or an Upsize Permitted Senior Debt Hedging Instrument as set forth in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement.

Upsize Senior Creditor Group Representative” means a Senior Creditor Group Representative that is party to the Common Terms Agreement as of the Upsize Closing Date and which is identified as such on Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement.

Upsized Senior Debt” means the Senior Debt Obligations owing under the Credit Facility Agreement as of the Upsize Closing Date.

Upsized Senior Debt Commitments” means the Senior Debt Commitments identified as such in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement as of the Upsize Closing Date.

Upsized Senior Debt Instrument” means each Senior Debt Instrument identified as such in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement as of the Upsize Closing Date.

Upsized Senior Debt Obligations” means the Senior Debt Obligations under the Upsized Senior Debt Instruments.

US Dollars” and “$” means the currency of the United States.

US Tax Compliance Certificate” has the meaning given in Section 21.5(b)(ii)(C) (Status of Facility Lenders and Facility Agents) of the Common Terms Agreement.

 

-288-

Plaquemines – Amended & Restated Common Terms Agreement


USA Patriot Act” means the Uniting and Strengthening America by Providing Appropriate Tools Required to Intercept and Obstruct Terrorism Act of 2001, as amended from time to time.

USPTO” means the United States Patent and Trademark Office.

Weeks-Massman” means Weeks-Massman, A Joint Venture, a general partnership between Weeks Marine, Inc. and Massman Construction Co.

Withdrawal and Transfer Certificate” means a certificate, in the form attached as Schedule K (Form of Withdrawal and Transfer Certificate) to the Common Security and Account Agreement.

Withdrawal Liability” means any liability to a Multiemployer Plan as a result of a complete or partial withdrawal from such Multiemployer Plan, as such terms are defined in Sections 4203 and 4205 of ERISA.

Working Capital Debt” has the meaning given in Section 6.2 (Working Capital Debt) of the Common Terms Agreement.

Working Capital Facility” has the meaning given in the Credit Facility Agreement.

Working Capital Lenders” has the meaning given in the Credit Facility Agreement.

Working Capital Loan Availability Period” has the meaning given in the Credit Facility Agreement.

Working Capital Loans” has the meaning given in the Credit Facility Agreement.

Write-Down and Conversion Powers” means, (a) with respect to any EEA Resolution Authority, the write-down and conversion powers of such EEA Resolution Authority from time to time under the Bail-In Legislation for the applicable EEA Member Country, which write-down and conversion powers are described in the EU Bail-In Legislation Schedule, and (b) with respect to the United Kingdom, any powers of the applicable Resolution Authority under the Bail-In Legislation to cancel, reduce, modify or change the form of a liability of any UK Financial Institution or any contract or instrument under which that liability arises, to convert all or part of that liability into shares, securities or obligations of that person or any other person, to provide that any such contract or instrument is to have effect as if a right had been exercised under it or to suspend any obligation in respect of that liability or any of the powers under that Bail-In Legislation that are related to or ancillary to any of those powers.

 

-289-

Plaquemines – Amended & Restated Common Terms Agreement


Louisiana Defined Terms. As used in the Common Terms Agreement, the Common Security and Account Agreement or another Finance Document, but without intending to alter or derogate from the choice of applicable law set forth in Section 23.12 of the Common Terms Agreement or in another provision of a Finance Document, the following terms have the following meanings: “real property” and “real estate” shall include immovable property; “fee simple” shall include full ownership; “personal property” shall include movable property; “tangible property” shall include corporeal property; “intangible property” shall include incorporeal property; “easements” shall include servitudes; “buildings” shall be deemed to include other constructions; “county” shall include a parish; the term “joint and several liability” and words of similar import shall be deemed to include in solido liability; and references to the UCC or the Uniform Commercial Code shall include the Louisiana Commercial Laws, La. R.S. §§ 10:1-101 et seq.

 

-290-

Plaquemines – Amended & Restated Common Terms Agreement


SCHEDULE B-1

DISBURSEMENT REQUEST FORM (TERM LOANS)

[Omitted]


SCHEDULE B-2

DISBURSEMENT REQUEST FORM (WORKING CAPITAL LOANS)

[Omitted]


SCHEDULE B-3

ISSUANCE REQUEST FORM (LETTERS OF CREDIT)

[Omitted]


SCHEDULE C-1

TABLE OF REQUIREMENTS FOR LEGAL OPINIONS – CONDITIONS TO INITIAL CLOSING

[Omitted]


SCHEDULE C-2

TABLE OF REQUIREMENTS FOR LEGAL OPINIONS – CONDITIONS TO UPSIZE CLOSING

[Omitted]


SCHEDULE D-1

FORM OF CONSTRUCTION BUDGET

[Omitted]


SCHEDULE D-2

FORM OF CONSTRUCTION SCHEDULE

[Omitted]


SCHEDULE E

KNOW YOUR CUSTOMER DOCUMENTATION

[Omitted]


SCHEDULE F

MATERIAL PERMITS

[Omitted]


SCHEDULE G

DISCLOSURE SCHEDULE

[Omitted]


SCHEDULE H

MATERIAL PROJECT AGREEMENTS AND CERTAIN OTHER CONTRACTS

[Omitted]


SCHEDULE I

CHANGE ORDERS

[Omitted]


SCHEDULE J

[RESERVED]

 

J-1


SCHEDULE K

GAS SOURCING PLAN

[Omitted]


SCHEDULE L

SCHEDULE OF MINIMUM INSURANCE

[Omitted]


SCHEDULE M

INDEPENDENT INSURANCE EXPERTS

[Omitted]


SCHEDULE N

SENIOR CREDITORS’ ADVISORS AND CONSULTANTS

[Omitted]


SCHEDULE O-1

PHASE 1 LENDERS’ RELIABILITY TEST CRITERIA

[Omitted]


SCHEDULE O-2

LENDERS’ RELIABILITY TEST CRITERIA

[Omitted]


SCHEDULE P-1

REPLACEMENT FACILITY AGENT ACCESSION AGREEMENT

[Omitted]


SCHEDULE P-2

NEW FACILITY AGENT ACCESSION AGREEMENT (ADDITIONAL SENIOR DEBT)

[Omitted]


SCHEDULE Q-1

ADDRESSES FOR NOTICES TO OBLIGORS

[Omitted]


SCHEDULE Q-2

ADDRESSES FOR NOTICES TO FACILITY AGENTS AND FACILITY LENDERS

[Omitted]


SCHEDULE R

BASE CASE FORECAST

[Omitted]


SCHEDULE S-1

FORM OF GENERAL SUBORDINATION AGREEMENT

[Omitted]


SCHEDULE S-2

FORM OF OBLIGOR SUBORDINATION AGREEMENT

[Omitted]


SCHEDULE T

KNOWLEDGE PARTIES

(Definition of “Knowledge” – Schedule A to the Common Terms Agreement)

 

Name

  

Title

Michael Sabel

   Chief Executive Officer of the Sponsor

Jonathan Thayer

   Chief Financial Officer

Keith Larson

   General Counsel

Fory Musser

   Senior Vice President, Development

Tom Newton

   Senior Vice President, Engineering of the Sponsor

Leah Woodward

   Treasurer

 

T-1

Plaquemines – Amended and Restated Common Terms Agreement Schedules


SCHEDULE U

REAL PROPERTY DOCUMENTS

(Definition of “Real Property Documents” – Schedule A to the Common Terms Agreement)

 

1.

Ground Lease Agreement (Parcel 2), dated as of July 19, 2021, between Venture Global Plaquemines LNG, LLC and The Plaquemines Port Harbor and Terminal District.

 

2.

Ground Lease Agreement (Laydown Area), dated as of July 19, 2021, between Venture Global Plaquemines LNG, LLC and The Plaquemines Port Harbor and Terminal District.

 

U-1

Plaquemines – Amended and Restated Common Terms Agreement Schedules


SCHEDULE V

SCHEDULE OF CERTAIN REAL PROPERTY RIGHTS

[Omitted]


SCHEDULE W

FORM OF DISBURSEMENT ENDORSEMENT

[Omitted]


SCHEDULE X

PHASE I ENVIRONMENTAL ASSESSMENTS

[Omitted]


SCHEDULE Y

DISQUALIFIED INSTITUTIONS

(Definition of “Disqualified Institution” – Schedule A to the Common Terms Agreement)

[Omitted]


SCHEDULE Z

DISQUALIFIED ADVISORS

(Definition of “Disqualified Advisors” – Schedule A to the Common Terms Agreement)

[Omitted]


SCHEDULE AA

SURVEY ENDORSEMENTS

(Definitions “Survey Endorsements” – Schedule A to the Common Terms Agreement)

 

1.    ALTA 9.7-06    Restrictions, Encroachments, Minerals – Land Under Development
2.    ALTA 17-06    Access and Entry
3.    ALTA 17.2-06    Utility Access
4.    ALTA 19.1-06    Contiguity-Single Parcel
5.    ALTA 25-06    Same as Survey

 

AA-1

Plaquemines – Amended and Restated Common Terms Agreement Schedules


SCHEDULE BB

SHIPPING AGENCY TERM SHEET

[Omitted]


SCHEDULE 5.1(F)(II)

PRIOR LOCATIONS

[Omitted]


SCHEDULE 5.2(M)

REAL PROPERTY INTERESTS

[Omitted]

Exhibit 10.88

Execution Version

AMENDMENT NO. 1 TO THE COMMON TERMS AGREEMENT

This AMENDMENT NO. 1 TO THE COMMON TERMS AGREEMENT (this “Amendment”), dated as of September 29, 2023, is in respect of the Amended & Restated Common Terms Agreement, dated as of March 13, 2023 (as amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”), by and among Venture Global Plaquemines LNG, LLC, a Delaware limited liability company (the “Borrower”), Venture Global Gator Express, LLC (the “Guarantor”), Natixis, New York Branch, as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties (in such capacity, the “Credit Facility Agent”), each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Royal Bank of Canada, as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”). Reference is also made to the Amended & Restated Credit Facility Agreement, dated as of March 13, 2023 (as amended, amended and restated, modified or supplemented from time to time, the “Credit Facility Agreement”), by and among the Borrower, the Guarantor, the Lenders party thereto from time to time, the Issuing Banks party thereto from time to time, the Credit Facility Agent, and solely for purposes of Section 3.06 thereof, Royal Bank of Canada, as Collateral Agent (in such capacity, the “Collateral Agent”). All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Common Terms Agreement, or if not defined therein, the Credit Facility Agreement. For all purposes of this Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.

WHEREAS, the Borrower has requested that the Credit Facility Lenders under the Credit Facility Agreement (collectively, the “Lenders” and each individually, a “Lender”), the Credit Facility Agent and the Intercreditor Agent consent and agree, and the Lenders constituting the Required Lenders, the Credit Facility Agent and the Intercreditor Agent are willing to consent and agree, to amend the Common Terms Agreement on the terms and conditions set forth herein and in accordance with Section 23.15 of the Common Terms Agreement, Section 4 of the Intercreditor Agreement and Section 11.01 of the Credit Facility Agreement.

NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1. Amendment. Upon the effectiveness of this Amendment in accordance with Section 2 below, each of the Lenders party hereto, the Credit Facility Agent (at the direction of Required Lenders) and the Intercreditor Agent hereby consent and agree to amend the Common Terms Agreement as follows:

1.1 Section 8.7 (DPU Shipping Agreement) of the Common Terms Agreement shall be amended by replacing the reference to “September 30, 2023” with “December 31, 2023”.

1.2 Section 10.2 (Quarterly Historical DSCR Certificate) of the Common Terms Agreement shall be amended by replacing the reference to “15 Business Days” with “30 days”.


Section 2. Effectiveness. This Amendment shall become effective as of the date hereof only upon delivery of executed counterparts of this Amendment by each of (a) the Borrower, (b) the Guarantor, (c) the Intercreditor Agent, (d) the Credit Facility Agent (who constitutes the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement)) and (e) Lenders constituting the Required Lenders under the Credit Facility Agreement.

Section 3. Representations and Warranties. Each of the Obligors hereby represents and warrants to the Lenders, Credit Facility Agent and Intercreditor Agent that:

3.1 upon the effectiveness of the amendments set forth in Section 1, no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing or will result from the consummation of the transactions contemplated by this Amendment; and

3.2 upon the effectiveness of the amendments set forth in Section 1, each of the representations and warranties of the Obligors in the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents is true and correct in all material respects except (A) for those representations and warranties that are qualified by materiality, which are true and correct in all respects on and as of the date hereof (or, if stated to have been made solely as of an earlier date, as of such earlier date) and (B) for the representations and warranties set forth in Section 5.1 (Initial Representations and Warranties of the Obligors) of the Common Terms Agreement, which were made only on the Upsize Closing Date.

Section 4. Finance Document. This Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement. Each of the parties hereto agree that each reference to “Common Terms Agreement” in each Finance Document, including the Intercreditor Agreement and Credit Facility Agreement, shall refer to the Common Terms Agreement as amended hereby.

Section 5. Governing Law. THIS AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA.

Section 6. Headings. All headings in this Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.

Section 7. Binding Nature and Benefit; Amendment. This Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 8. Counterparts. This Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Amendment.

 

2


Section 9. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Amendment apply to any other matters.

Section 10. E-Signature. The words “execution,” “signed,” “signature,” and words of like import in this Amendment shall be deemed to include electronic signatures or electronic records, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any legal requirements, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

Section 11. Direction to Credit Facility Agent and Intercreditor Agent.

11.1 By their signature below, each of the undersigned Credit Facility Lenders (collectively constituting the Required Lenders) instructs the Credit Facility Agent to (i) execute this Amendment and (ii) direct the Intercreditor Agent to execute this Amendment; and

11.2 Based on the instructions above, the Credit Facility Agent, constituting the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement), hereby directs the Intercreditor Agent to execute this Amendment.

[Remainder of the page left intentionally blank.]

 

3


IN WITNESS WHEREOF, the Parties have caused this Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC,

as the Borrower

By:   /s/ Leah Woodward
Name: Leah Woodward
Title: Treasurer
VENTURE GLOBAL GATOR EXPRESS, LLC,
as the Guarantor
By:   /s/ Leah Woodward
Name: Leah Woodward
Title: Treasurer

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

NATIXIS, NEW YORK BRANCH,

as Credit Facility Agent

By:   /s/ Katarina Janosikova /s/ Lisa Wong
Name: Katarina Janosikova  Name: Lisa Wong
Title: Director        Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

ROYAL BANK OF CANADA,

as Intercreditor Agent

By:   /s/ Annie Lee
Name: Annie Lee
Title: Manager, Agency Services

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

Aozora Bank, Ltd.,

as Lender

By:   /s/ Hirokaza Aoyama
Name: Hirokaza Aoyama
Title: Senior Vice President and Group Head

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

ASSOCIATED BANK, N.A.,

as Lender

By:   /s/ Justin Nam
Name: Justin Nam
Title: Senior Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

BANK OF AMERICA, N.A.,

as Lender

By:   /s/ Ronald McKaig
Name: Ronald McKaig
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

Bank of China, New York Branch,

as Lender

By:   /s/ Raymond Qiao
Name: Raymond Qiao
Title: Executive Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

BAYERISCHE LANDESBANK, NEW YORK BRANCH,

as Lender

By:   /s/ Kareem Hartl
Name: Kareem Hartl
Title: Vice President
By:   /s/ Elke Videgain
Name: Elke Videgain
Title: Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

THE BANK OF NOVA SCOTIA, HOUSTON BRANCH,

as Lender

By:   /s/ Joe Lattanzi
Name: Joe Lattanzi
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

BANCO DE SABADELL, S.A., MIAMI BRANCH,

as Lender

By:   /s/ Enrique Castillo
Name: Enrique Castillo
Title: Head of Corporate Banking

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set
forth above.

Banco Santander, S.A,

as Lender

By:   /s/ Arturo Prieto
Name: Arturo Prieto
Title: Managing Director
By:   /s/ Marcos Garcia Garcia
Name: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

BANK GOSPODARSTWA KRAJOWEGO,

as Lender

By:   /s/ Wojciech Kryjak  /s/ Maryia Posyniak
Name: Wojciech Kryjak  Name: Maryia Posyniak
Title: Pełnomocnik    Title: Pełnomocnik

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

DZ BANK AG Deutsche Zentral Genossenschaftsbank, New York Branch,

as Lender

By:   /s/ Glenn R. Patterson
Name: Glenn R. Patterson
Title: Director
By:   /s/ John Hammarskjold
Name: John Hammarskjold
Title: Senior Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

DEUTSCHE BANK AG, NEW YORK BRANCH,

as Lender

By:   /s/ Jeremy Eisman
Name: Jeremy Eisman
Title: Managing Director
By:   /s/ Blake Yaralian
Name: Blake Yaralian
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set
forth above.

Federated Hermes Project and Trade Finance Tender Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

First-Citizens Bank & Trust Company,

as Lender

By:   /s/ Stephen Norcross
Name: Stephen Norcross
Title: Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

FIRSTBANK PUERTO RICO d/b/a FIRSTBANK FLORIDA,

as Lender

By:   /s/ Kevin P. Flynn
Name: Kevin P. Flynn
Title: SVP, Corporate Banking Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

GOLDMAN SACHS BANK USA,

as Lender

By:   /s/ Dan Martis
Name: Dan Martis
Title: Authorized Signatory

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

Hamburg Commercial Bank AG,

as Lender

By:   /s/ Marco Lorenzen
Name: Marco Lorenzen
Title: Vice President
By:   /s/ Tobias Kerrmann
Name: Tobias Kerrmann
Title: Associate

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

ING Capital LLC,

as Lender

By:   /s/ Subha Pasumarti
Name: Subha Pasumarti
Title: Managing Director
By:   /s/ Catharina van der Woude
Name: Catharina van der Woude
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set
forth above.

JPMORGAN CHASE BANK, N.A.,

as Lender

By:   /s/ Arina Mavilian
Name: Arina Mavilian
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

KfW IPEX-Bank GmbH,

as Lender

By:   /s/ Simone Thrun  /s/ Dorothee Schwenk
Name: Simone Thrun  Name: Dorothee Schwenk
Title: Director     Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

LANDESBANK BADEN-WÜRTTEMBERG, NEW YORK BRANCH,

as Lender

By:   /s/ A. Bruns
Name: A. Bruns
Title: Director
By:   /s/ O. Langel
Name: O. Langel
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

LANDESBANK HESSEN-THÜRINGEN GIROZENTRALE, NEW YORK BRANCH,

as Lender

By:   /s/ Manuel Liebers
Name: Manuel Liebers
Title: Vice President
By:   /s/ Ralf Goebel
Name: Ralf Goebel
Title: Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

Mizuho Bank, Ltd.,

as Lender

By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

MUFG Bank Ltd.,

as Lender

By:   /s/ John K. Smith
Name: John K. Smith
Title: Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

NATIONAL BANK OF CANADA,

as Lender

By:   /s/ John Hunt
Name: John Hunt
Title: Authorized Signatory
By:   /s/ Mark Williamson
Name: Mark Williamson
Title: Authorized Signatory

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

Natixis, New York Branch,

as Lender

By:   /s/ Amit Roy
Name: Amit Roy
Title: Managing Director
By:   /s/ James B. Kaiser
Name: James B. Kaiser
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

Nonghyup Bank Hong Kong Branch,

as Lender

By:   /s/ Yong Jae, YOU
Name: Yong Jae, YOU
Title: General Manager

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

[Nomura Corporate Funding Americas, LLC],

as Lender

By:   /s/ Vinod Mukani
Name: Vinod Mukani
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

Project and Trade Finance Core Fund,

as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

RAYMOND JAMES BANK,

as Lender

By:   /s/ Robert F. Moyle
Name: Robert F. Moyle
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

Regions Bank,

as Lender

By:   /s/ Daniel Capps
Name: Daniel Capps
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

Royal Bank of Canada,

as Lender

By:   /s/ Don J. McKinnerney
Name: Don J. McKinnerney
Title: Authorized Signatory

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

RV AIP S.C.S SICAV-SIF with respect to its sub-fund, RV AIP S.C.S SICAV-SIF RV TF2 Infra Debt, acting through its AIFM and general partner, R+V AIFM S.à r.I.,

as Lender

By:   /s/ Anna-Maria Musch
Name: Anna-Maria Musch
Title: Conducting Officer
By:   /s/ Alexander Endrikat
Name: Alexander Endrikat
Title: Conducting Officer

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

Shinhan Bank New York Branch,

as Lender

By:   /s/ Jun Ho Lee
Name: Jun Ho Lee
Title: Deputy General Manager

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

SPT INFRASTRUCTURE FINANCE SUB-4, LLC,

as Lender

By:   /s/ Heig Najaria
Name: Heig Najaria
Title: Authorized Signatory

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

TRUIST BANK,

as Lender

By:   /s/ Bryan Kunitake
Name: Bryan Kunitake
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

WELLS FARGO BANK, N.A.,

as Lender

By:   /s/ Nathan Starr
Name: Nathan Starr
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA


Acknowledged and agreed as of the first date set forth above.

[Woori Global Markets Asia Limited],

as Lender

By:   /s/ Soojin Lee
Name: Soojin Lee
Title: Chief Executive

 

SIGNATURE PAGE TO AMENDMENT NO. 1 TO CTA

Exhibit 10.89

Execution Version

AMENDMENT NO. 2 TO THE COMMON TERMS AGREEMENT AND AMENDMENT NO. 1 TO THE COMMON SECURITY AND ACCOUNT AGREEMENT

This AMENDMENT NO. 2 TO THE COMMON TERMS AGREEMENT AND AMENDMENT NO. 1 TO THE COMMON SECURITY AND ACCOUNT AGREEMENT (this “Amendment”), dated as of May 15, 2024 is in respect of (a) the Amended & Restated Common Terms Agreement, dated as of March 13, 2023 (as amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”), by and among Venture Global Plaquemines LNG, LLC, a Delaware limited liability company (the “Borrower”), Venture Global Gator Express, LLC (the “Guarantor”), Natixis, New York Branch, as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties (in such capacity, the “Credit Facility Agent”), each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Royal Bank of Canada, as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”), as amended by that certain Amendment No. 1 to the Common Terms Agreement, dated as of September 29, 2023, and (b) the Amended & Restated Common Security and Account Agreement, dated as of March 13, 2023 (as amended, amended and restated, modified or supplemented from time to time, the “Common Security and Account Agreement”), by and among the Borrower, the Guarantor, City National Bank, as the account bank, the Intercreditor Agent, Royal Bank of Canada, as Collateral Agent (in such capacity, the “Collateral Agent”) and the Senior Creditor Group Representatives party thereto from time to time. Reference is also made to the Amended & Restated Credit Facility Agreement, dated as of March 13, 2023 (as amended, amended and restated, modified or supplemented from time to time, the “Credit Facility Agreement”), by and among the Borrower, the Guarantor, the Lenders party thereto from time to time, the Issuing Banks party thereto from time to time, the Credit Facility Agent, and solely for purposes of Section 3.06 thereof, the Collateral Agent. All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Common Terms Agreement, or if not defined therein, the Credit Facility Agreement. For all purposes of this Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.

WHEREAS, the Borrower has requested that the Credit Facility Lenders under the Credit Facility Agreement (collectively, the “Lenders” and each individually, a “Lender”), the Credit Facility Agent, the Collateral Agent and the Intercreditor Agent consent and agree, and the Lenders constituting the Required Lenders, the Credit Facility Agent, the Collateral Agent and the Intercreditor Agent are willing to consent and agree, to amend the Common Terms Agreement and the Common Security and Account Agreement on the terms and conditions set forth herein and in accordance with Section 23.15 of the Common Terms Agreement, Section 4 of the Intercreditor Agreement, Section 11.01 of the Credit Facility Agreement, Section 7.2(a)(i)(A) (Modification Approval Levels) of the Common Security and Account Agreement and Section 12.14 (Amendments) of the Common Security and Account Agreement.


NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1. Amendment.

1.1 Amendment to Common Terms Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, each of the Lenders party hereto, the Credit Facility Agent (at the direction of Required Lenders) and the Intercreditor Agent hereby consent and agree to amend the Common Terms Agreement as follows:

(a) The definition of “Permitted Hedging Instrument” in Section 1.3 (Definitions) of Schedule A (Common Definitions and Rules of Interpretation) to the Common Terms Agreement shall be deleted in its entirety and replaced with the following:

“Permitted Hedging Instrument” means (a) each Initial Permitted Senior Debt Hedging Instrument; (b) each Upsize Permitted Senior Debt Hedging Instrument or (c) a Hedging Instrument entered into by the Borrower in the ordinary course of business, including any Hedging Instrument entered into in connection with forward sale or factoring contracts related to Pre-Completion Revenues, and that (i) is with a Hedging Bank, a Gas Hedge Provider or any other party that is a counterparty to a Hedging Instrument, and (ii) is entered for non-speculative purposes and is on arm’s-length terms; provided that if such Hedging Instrument is a Gas Hedging Instrument, it is for a period not to exceed the three prompt month contracts (or in the case of Basis Swaps, thirty six months) and the aggregate quantum under all (1) Futures Contracts, Fixed-Floating Futures Swaps, NYMEX Natural Gas Futures Contracts and Swing Swaps does not exceed 207.5 TBtu of gas utilizing intra-month and up to 24 prompt month contracts, (2) Index Swaps does not exceed 98.8 TBtus per month of gas utilizing up to 24 prompt month contracts, and (3) Basis Swaps does not exceed 98.8 TBtu per month with a tenor up to 60 months, where the limitations in each of the categories described in sub-clauses (1), (2) and (3) are not aggregated. “Permitted Hedging Instrument” includes any “Permitted Senior Debt Hedging Instrument.” For the avoidance of doubt, each Anticipatory Hedge shall constitute (i) a Permitted Hedging Instrument and (ii) upon the relevant counterparty acceding to the Common Security and Account Agreement, a Permitted Senior Debt Hedging Instrument, in each case for all purposes hereunder and under the other Transaction Documents. As used in the preceding sentence, “Anticipatory Hedge” means any interest rate transaction between a Hedging Bank and Venture Global LNG, Inc. or the Borrower entered into prior to the Initial Closing Date, and any Hedging Instrument entered into between a Hedging Bank and the Borrower, which results from an assignment, novation, participation, or any other conveyance or transfer of an Anticipatory Hedge (including any restructuring thereof or offsetting transactions related thereto) to the Borrower.

(b) Item 3. of Schedule K (Gas Sourcing Plan) of the Common Terms Agreement shall be deleted in its entirety and replaced with the following:

Prior to September 30, 2025, the Borrower shall have entered into cumulative arrangements for at least 1,000,000 MMBtu/d of firm natural gas supply for the Project for a minimum term of one (1) year starting from January 1, 2026.

 

2


1.2 Administrative Amendment to Common Security and Account Agreement. Upon the effectiveness of this Amendment in accordance with Section 2 below, the Collateral Agent (at the direction of the Intercreditor Agent) hereby consents and agrees to amend the Common Security and Account Agreement as follows:

“Permitted Hedging Instrument” means (a) each Initial Permitted Senior Debt Hedging Instrument; (b) each Upsize Permitted Senior Debt Hedging Instrument or (c) a Hedging Instrument entered into by the Borrower in the ordinary course of business, including any Hedging Instrument entered into in connection with forward sale or factoring contracts related to Pre-Completion Revenues, and that (i) is with a Hedging Bank, a Gas Hedge Provider or any other party that is a counterparty to a Hedging Instrument, and (ii) is entered for non-speculative purposes and is on arm’s-length terms; provided that if such Hedging Instrument is a Gas Hedging Instrument, it is for a period not to exceed the three prompt month contracts (or in the case of Basis Swaps, thirty six months) and the aggregate quantum under all (1) Futures Contracts, Fixed-Floating Futures Swaps, NYMEX Natural Gas Futures Contracts and Swing Swaps does not exceed 207.5 TBtu of gas utilizing intra-month and up to 24 prompt month contracts, (2) Index Swaps does not exceed 98.8 TBtus per month of gas utilizing up to 24 prompt month contracts, and (3) Basis Swaps does not exceed 98.8 TBtu per month with a tenor up to 60 months, where the limitations in each of the categories described in sub-clauses (1), (2) and (3) are not aggregated. “Permitted Hedging Instrument” includes any “Permitted Senior Debt Hedging Instrument.” For the avoidance of doubt, each Anticipatory Hedge shall constitute (i) a Permitted Hedging Instrument and (ii) upon the relevant counterparty acceding to the Common Security and Account Agreement, a Permitted Senior Debt Hedging Instrument, in each case for all purposes hereunder and under the other Transaction Documents. As used in the preceding sentence, “Anticipatory Hedge” means any interest rate transaction between a Hedging Bank and Venture Global LNG, Inc. or the Borrower entered into prior to the Initial Closing Date, and any Hedging Instrument entered into between a Hedging Bank and the Borrower, which results from an assignment, novation, participation, or any other conveyance or transfer of an Anticipatory Hedge (including any restructuring thereof or offsetting transactions related thereto) to the Borrower.

Section 2. Effectiveness. This Amendment shall become effective as of the date hereof only upon delivery of executed counterparts of this Amendment by each of (a) the Borrower, (b) the Guarantor, (c) the Intercreditor Agent, (d) the Collateral Agent, (e) the Credit Facility Agent (who constitutes the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement)) and (f) Lenders constituting the Required Lenders under the Credit Facility Agreement.

Section 3. Representations and Warranties. Each of the Obligors hereby represents and warrants to the Lenders, Credit Facility Agent, the Collateral Agent and Intercreditor Agent that:

3.1 upon the effectiveness of the amendments set forth in Section 1, no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing or will result from the consummation of the transactions contemplated by this Amendment; and

 

3


3.2 upon the effectiveness of the amendments set forth in Section 1, each of the representations and warranties of the Obligors in the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents is true and correct in all material respects except (A) for those representations and warranties that are qualified by materiality, which are true and correct in all respects on and as of the date hereof (or, if stated to have been made solely as of an earlier date, as of such earlier date) and (B) for the representations and warranties set forth in Section 5.1 (Initial Representations and Warranties of the Obligors) of the Common Terms Agreement, which were made only on the Upsize Closing Date.

Section 4. Finance Document. This Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement. Each of the parties hereto agree that (i) each reference to “Common Terms Agreement” in each Finance Document, including the Intercreditor Agreement and Credit Facility Agreement, shall refer to the Common Terms Agreement as amended hereby and (ii) each reference to “Common Security and Account Agreement” in each Finance Document, including the Intercreditor Agreement and Credit Facility Agreement, shall refer to the Common Security and Account Agreement as amended hereby.

Section 5. Governing Law. THIS AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA.

Section 6. Headings. All headings in this Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.

Section 7. Binding Nature and Benefit; Amendment. This Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 8. Counterparts. This Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Amendment.

Section 9. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Common Terms Agreement, the Common Security and Account Agreement, the Credit Facility Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Amendment apply to any other matters.

 

4


Section 10. E-Signature. The words “execution,” “signed,” “signature,” and words of like import in this Amendment shall be deemed to include electronic signatures or electronic records, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any legal requirements, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

Section 11. Direction to Credit Facility Agent, Intercreditor Agent and Collateral Agent.

11.1 By their signature below, each of the undersigned Credit Facility Lenders (collectively constituting the Required Lenders) instructs the Credit Facility Agent to (i) execute this Amendment and (ii) direct the Intercreditor Agent to execute this Amendment; and

11.2 Based on the instructions in Section 11.1, the Credit Facility Agent, constituting the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement), hereby directs the Intercreditor Agent to execute this Amendment.

11.3 The Borrower hereby confirms that the amendment contemplated in Section 1.2 is an Administrative Decision within the meaning of Schedule 2 to the Intercreditor Agreement and hereby requests that the Intercreditor Agent provide a direction to the Collateral Agent in accordance with Section 7.2(a)(i)(A) (Modification Approval Levels) and Section 12.14 (Amendments) of the Common Security and Account Agreement to execute this Amendment.

11.4 Based on the certification in Section 11.3, the Intercreditor Agent hereby directs the Collateral Agent to execute this Amendment.

[Remainder of the page left intentionally blank.]

 

5


IN WITNESS WHEREOF, the Parties have caused this Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL PLAQUEMINES LNG, LLC,
as the Borrower
By:   /s/ Keith Larson
Name: Keith Larson
Title: General Counsel
VENTURE GLOBAL GATOR EXPRESS, LLC,
as the Guarantor
By:   /s/ Keith Larson
Name: Keith Larson
Title: General Counsel

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set
forth above.
NATIXIS, NEW YORK BRANCH,
as Credit Facility Agent
By:   /s/ Katarina Janosikova
Name: Katarina Janosikova
Title: Director
By:   /s/ Lisa Wong
Name: Lisa Wong
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
ROYAL BANK OF CANADA,
as Intercreditor Agent
By:   /s/ Richard Dsouza
Name: Richard Dsouza
Title: Manager Agency Services

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
ROYAL BANK OF CANADA,
as Collateral Agent
By:   /s/ Richard Dsouza
Name: Richard Dsouza
Title: Manager Agency Services

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
Aozora Bank, Ltd.,
as Lender
By:   /s/ Hirokazi Aoyama
Name: Hirokazi Aoyama
Title: Senior Vice President & Group Head

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
ASSOCIATED BANK, N.A.,
as Lender
By:   /s/ Laurynas Kubilius
Name: Laurynas Kubilius
Title: Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
BANCO SANTANDER, S.A,
as Lender
By:   /s/ Arturo Prieto
Name: Arturo Prieto
Title: MD
By:   /s/ Ignacio Ruiz de Assin
Name: Ignacio Ruiz de Assin
Title: VP

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
Bank Gospodarstwa Krajowego
as Lender
By:   /s/ Wojciech Kryjak   /s/ Dariusz Hoiubowicz
Name: Wojciech Kryjak   Name: Dariusz Hoiubowicz
Title: Pełnomocnik   Title: Proxy

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.

BANK OF AMERICA, N.A.,

as Lender

By:   /s/ Ronald E. McKaig
Name: Ronald E. McKaig
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
Bank of China, New York Branch,
as Lender
By:   /s/ Raymond Qiao
Name: Raymond Qiao
Title: Executive Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
Bayerische Landesbank, New York Branch,
as Lender
By:   /s/ Kareem Hartl
Name: Kareem Hartl
Title: Vice President
By:   /s/ Elke Videgain
Name: Elke Videgain
Title: Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
CAIXABANK,
as Lender
By:   /s/ Jorg Hahn
Name: Jorg Hahn
By:   /s/ Maria Luisa Muñoz
Name: Maria Luisa Muñoz

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.

Federated Hermes Project and Trade

Finance Tender Fund, as Lender

By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Senior Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
Goldman Sachs Bank USA,
as Lender
By:   /s/ Priyankush Goswami
Name: Priyankush Goswami
Title: Authorized Signatory

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
ING Capital, LLC
as Lender
By:   /s/ Subha Pasumarti
Name: Subha Pasumarti
Title: MD
ING Capital, LLC
as Lender
By:   /s/ Anthony Rivera
Name: Anthony Rivera
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
JPMORGAN CHASE BANK, N.A.,
as Lender
By:   /s/ Arina Mavilian
Name: Arina Mavilian
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
[], KfW IPEX-Bank GmbH
as Lender
By:   /s/ Ann-Kathrin Weber  /s/ Markus Schmidt
Name: Ann-Kathrin Weber   Name: Markus Schmidt
Title: Vice President   Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
LANDESBANK BADEN-WÜRTTEMBERG, NEW YORK BRANCH

[]

as Lender

By:   /s/ Arndt Bruns
Name: Arndt Bruns
Title: Director
By:   /s/ Michael Thier
Name: Michael Thier
Title: Executive Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
LANDESBANK HESSEN-THÜRINGEN GIROZENTRALE, NEW YORK BRANCH,
as Lender
By:   /s/ Manuel Liebers
Name: Manuel Liebers
Title: Vice President
By:   /s/ Ralf Goebel
Name: Ralf Goebel
Title: Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
MIZUHO BANK, LTD.,
as Lender
By:   /s/ Dominick D’Ascoli
Name: Dominick D’Ascoli
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
NATIONAL BANK OF CANADA,
as Lender
By:   /s/ Andrew Nguyen
Name: Andrew Nguyen
Title: Authorized Signatory
By:   /s/ John Hunt
Name: John Hunt
Title: Authorized Signatory

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.

Natixis, New York Branch

as Lender

By:   /s/ Amit Roy
Name: Amit Roy
Title: Managing Director
By:   /s/ Nasir Khan
Name: Nasir Khan
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
Nomura Corporate Funding Americas, LLC ,
As Lender
By:   /s/ Vinod Mukani
Name: Vinod Mukani
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
NORDDEUTSCHE LANDESBANK
GIROZENTRALE, NEW YORK BRANCH,
as Lender
By:   /s/ Geoffrey Mrema
Name: Geoffrey Mrema
By:   /s/ Anna Hutto
Name: Anna Hutto

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
Project and Trade Finance Core Fund,
as Lender
By:   /s/ Christopher P. McGinley
Name: Christopher P. McGinley
Title: Senior Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as ofthe first date set forth above.

Regions Bank,

as Lender

By:   /s/ Daniel Capps
Name: Daniel Capps
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.

ROYAL BANK OF CANADA,

as Lender

By:   /s/ Don J. McKinnerney
Name: Don J. McKinnerney
Title: Authorized Signatory

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
RV AIP S.C.S. SICAV-SIF RV TF 2 Infra Debt, acting through its general partner R+V AIFM S.à r.l.,
as Lender
By:   /s/ Anna-Maria Musch
Name: Anna-Maria Musch
Title: Conducting Officer
By:   /s/ Olivier Kilan
Name: Olivier Kilan
Title: Conducting Officer

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
Sumitomo Mitsui Banking Corporation,
as Lender
By:   /s/ Brian Caldwell
Name: Brian Caldwell
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
SPT INFRASTRUCTURE FINANCE SUB-4, LLC,
as Lender
By:   /s/ Haig Najarian
Name: Haig Najarian
Title: Authorized Signatory

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
THE BANK OF NOVA SCOTIA, HOUSTON BRANCH,
as Lender
By:   /s/ Joe Lattanzi
Name: Joe Lattanzi
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
TRUIST BANK,
as Lender
By:   /s/ Benjamin L. Brown
Name: Benjamin L. Brown
Title: Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
WELLS FARGO BANK, N.A.,
as Lender
By:   /s/ Nathan Starr
Name: Nathan Starr
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
First-Citizens Bank & Trust Company,
as Lender
By:   /s/ Stephen Norcross
Name: Stephen Norcross
Title: Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA


Acknowledged and agreed as of the first date set forth above.
RAYMOND JAMES BANK,
as Lender
By:   /s/ Robert F. Moyle
Name: Robert F. Moyle
Title: Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 2 TO CTA

Exhibit 10.90

Execution Version

AMENDMENT NO. 3 TO THE COMMON TERMS AGREEMENT

This AMENDMENT NO. 3 TO THE COMMON TERMS AGREEMENT (this “Amendment”), dated as of October 23, 2024 is in respect of the Amended & Restated Common Terms Agreement, dated as of March 13, 2023 (as amended, amended and restated, modified or supplemented from time to time, the “Common Terms Agreement”), by and among Venture Global Plaquemines LNG, LLC, a Delaware limited liability company (the “Borrower”), Venture Global Gator Express, LLC (the “Guarantor”), Natixis, New York Branch, as the Credit Facility Agent on behalf of itself and the Credit Facility Lender Parties (in such capacity, the “Credit Facility Agent”), each other Facility Agent that is Party thereto from time to time on behalf of itself and the Facility Lenders under its Facility Agreement, and Royal Bank of Canada, as the Intercreditor Agent for the Facility Lenders (in such capacity, the “Intercreditor Agent”), as amended by that certain Amendment No. 1 to the Common Terms Agreement, dated as of September 29, 2023 and that certain Amendment No. 2 to the Common Terms Agreement and Amendment No. 1 to the Common Security and Account Agreement, dated as of May 15, 2024. Reference is also made to the Amended & Restated Credit Facility Agreement, dated as of March 13, 2023 (as amended, amended and restated, modified or supplemented from time to time, the “Credit Facility Agreement”), by and among the Borrower, the Guarantor, the Lenders party thereto from time to time, the Issuing Banks party thereto from time to time, the Credit Facility Agent, and solely for purposes of Section 3.06 thereof, Royal Bank of Canada, as Collateral Agent (in such capacity, the “Collateral Agent”). All capitalized terms used herein and not otherwise defined shall have the meanings ascribed to such terms in the Common Terms Agreement, or if not defined therein, the Credit Facility Agreement. For all purposes of this Amendment, except as otherwise expressly provided, the rules of interpretation set forth in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation) of the Common Terms Agreement are hereby incorporated by reference, mutatis mutandis, as if fully set forth herein.

WHEREAS, the Borrower has requested that the Credit Facility Lenders under the Credit Facility Agreement (collectively, the “Lenders” and each individually, a “Lender”), the Credit Facility Agent and the Intercreditor Agent consent and agree, and the Lenders constituting the Required Lenders, the Credit Facility Agent and the Intercreditor Agent are willing to consent and agree, to amend the Common Terms Agreement on the terms and conditions set forth herein and in accordance with Section 23.15 of the Common Terms Agreement, Section 4 of the Intercreditor Agreement and Section 11.01 of the Credit Facility Agreement.

NOW, THEREFORE, in consideration of the foregoing premises and the agreements, provisions and covenants herein contained, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows:

Section 1.  Amendment. Upon the effectiveness of this Amendment in accordance with Section 2 below, each of the Lenders party hereto, the Credit Facility Agent (at the direction of Required Lenders) and the Intercreditor Agent hereby consent and agree to amend the Common Terms Agreement as follows:


1.1 Section 4.3(a)(ii)(C) (Conditions to Each Term Loan Advance; Disbursement Request) of the Common Terms Agreement shall be deleted in its entirety and replaced with the following:

(C) (1) that the construction of the Project Facilities is proceeding substantially in accordance with the construction schedule set out in the Construction Budget and Schedule or, if not so proceeding, any delays shall, prior to the Project Phase 1 Completion Date, not be reasonably expected to cause the Project Phase 1 Completion Date to otherwise not be achieved by the Phase 1 LNG Facility Date Certain or not be reasonably expected to cause the Project Phase 2 Completion Date to otherwise not be achieved by the Phase 2 LNG Facility Date Certain and, after the Project Phase 1 Completion Date and prior to the Project Phase 2 Completion Date, not be reasonably expected to cause the Project Phase 2 Completion Date to otherwise not be achieved by the Phase 2 LNG Facility Date Certain, (2) as to the current utilization of previous Advances and (3) that, computed without duplication, the Facility Debt Commitments, funds on deposit in the Construction Account (including any Equity Funding remaining on deposit in the Construction Account), Contingency Reserve Account, the Phase 1 Pre-Completion Revenues Account (until the Project Phase 1 Completion Date), the Phase 2 Pre-Completion Revenues Account and the Permitted Finance Costs Reserve Account, and the projected contracted Cash Flow constituting Pre-Completion Revenues anticipated from the fixed component under LNG SPAs for the sale of Pre-Completion Quantities (including any confirmations related thereto) which are then in effect reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date, and with respect to the Project Phase 2 Completion Date and Phase 2 LNG Facility Date Certain only, the projected contracted Cash Flow from the fixed component under the Qualifying LNG SPAs reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date are sufficient to achieve the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain;

1.2 Section 5.2(t) (Sufficiency of Funds) of the Common Terms Agreement shall be deleted in its entirety and replaced with the following:

The Borrower reasonably believes that, computed without duplication, the Facility Debt Commitments, funds on deposit in the Construction Account (including any Equity Funding remaining on deposit in the Construction Account), Contingency Reserve Account, the Phase 1 Pre-Completion Revenues Account (until the Project Phase 1 Completion Date), the Phase 2 Pre-Completion Revenues Account and the Permitted Finance Costs Reserve Account, and the projected contracted Cash Flow constituting Pre- Completion Revenues anticipated from the fixed component under LNG SPAs for the sale of Pre-Completion Quantities (including any confirmations related thereto) which are then in effect reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date, and with respect to the Project Phase 2 Completion Date and Phase 2 LNG Facility Date Certain only, the projected contracted Cash Flow from the fixed component under the Qualifying LNG SPAs reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date shall be sufficient to achieve the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain.

 

2


1.3 Section 11.3(d) (Project Phase 1 Pre-Completion Revenue Restricted Payments) of the Common Terms Agreement shall be deleted in its entirety and replaced with the following:

(d) the Obligors have certified to the Credit Facility Agent, and the Independent Engineer has confirmed, that (A) computed without duplication, the Facility Debt Commitments, funds on deposit in the Construction Account (including any Equity Funding remaining on deposit in the Construction Account), Contingency Reserve Account (excluding the amount equal to the Contingency Reserve Amount as described in clause (a) of the definition thereof), the Phase 1 Pre-Completion Revenues Account (until the Project Phase 1 Completion Date), the Phase 2 Pre-Completion Revenues Account and the Permitted Finance Costs Reserve Account, and the projected contracted Cash Flow constituting Pre-Completion Revenues anticipated from the fixed component under LNG SPAs for the sale of Pre-Completion Quantities (including any confirmations related thereto) which are then in effect reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date, and with respect to the Project Phase 2 Completion Date and Phase 2 LNG Facility Date Certain only, the projected contracted Cash Flow from the fixed component under the Qualifying LNG SPAs reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date are sufficient to achieve (x) the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and (y) the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain and (B) the Borrower is reasonably expected to achieve (x) the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and (y) the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain;

1.4 Section 11.4(d)(i) (Project Phase 2 Pre-Completion Revenue Restricted Payments) of the Common Terms Agreement shall be deleted in its entirety and replaced with the following:

(i) (A) computed without duplication, the Facility Debt Commitments, funds on deposit in the Construction Account (including any Equity Funding remaining on deposit in the Construction Account), Contingency Reserve Account (excluding the amount equal to the Contingency Reserve Amount), the Phase 1 Pre-Completion Revenues Account (until the Project Phase 1 Completion Date), the Phase 2 Pre-Completion Revenues Account and the Permitted Finance Costs Reserve Account, and the projected contracted Cash Flow constituting Pre-Completion Revenues anticipated from the fixed component under LNG SPAs for the sale of Pre-Completion Quantities (including any confirmations related thereto) which are then in effect reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date, and with respect to the Project Phase 2 Completion Date and Phase 2 LNG Facility Date Certain only, the projected contracted Cash Flow from the fixed component under the Qualifying LNG SPAs reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date are sufficient to (x) achieve (I) if the Project Phase 1 Completion Date has not yet occurred, the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and (II) the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain and (y) after the Project Phase 1 Completion Date, pay any Phase 1 Reserve Amounts; and

 

3


1.5 Certification 7 in Schedule B-1 (Disbursement Request Form (Term Loans)) of the Common Terms Agreement shall be deleted in its entirety and replaced with the following:

7. Computed without duplication, the Facility Debt Commitments, funds on deposit in the Construction Account (including any Equity Funding remaining on deposit in the Construction Account), Contingency Reserve Account, the Phase 1 Pre-Completion Revenues Account (until the Project Phase 1 Completion Date), the Phase 2 Pre- Completion Revenues Account and the Permitted Finance Costs Reserve Account, and the projected contracted Cash Flow constituting Pre-Completion Revenues anticipated from the fixed component under LNG SPAs for the sale of Pre-Completion Quantities (including any confirmations related thereto) which are then in effect reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date, and with respect to the Project Phase 2 Completion Date and Phase 2 LNG Facility Date Certain only, the projected contracted Cash Flow from the fixed component under the Qualifying LNG SPAs reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date will be sufficient to achieve [the Project Phase 1 Completion Date by the Phase 1 LNG Facility Date Certain and]16 the Project Phase 2 Completion Date by the Phase 2 LNG Facility Date Certain;

Section 2. Effectiveness. This Amendment shall become effective as of the date hereof subject to satisfaction of the following conditions precedent:

2.1 delivery of executed counterparts of this Amendment by each of (a) the Borrower, (b) the Guarantor, (c) the Intercreditor Agent, (d) the Credit Facility Agent (who constitutes the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement)) and (e) Lenders constituting the Required Lenders under the Credit Facility Agreement;

2.2 the Intercreditor Agent and the Credit Facility Agent shall have received a certificate from the Borrower certifying that:

(a)

 

  (i)

the sum of (1) the Facility Debt Commitments, (2) funds on deposit in the Construction Account (including any Equity Funding remaining on deposit in the Construction Account), Contingency Reserve Account, the Phase 1 Pre-Completion Revenues Account, the Phase 2 Pre-Completion Revenues Account and the Permitted Finance Costs Reserve Account, (3) the projected contracted Cash Flow constituting Pre-Completion Revenues anticipated from the fixed component under LNG SPAs for the sale of Pre- Completion Quantities (including any confirmations related thereto) which are then in effect reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date, and (4) with respect to the Project Phase 2 Completion Date and Phase 2 LNG Facility Date Certain only, the projected contracted Cash Flow from the fixed component under the Qualifying LNG SPAs reasonably anticipated by Borrower to be received prior to the Project Phase 2 Completion Date, equals or exceeds

 

4


(ii) the amount of funds that are, as of the date hereof, reasonably required to achieve (x) the Project Phase 1 Completion Date and (y) the Project Phase 2 Completion Date (in each case, excluding any amounts required to be funded in the Senior Facilities Debt Service Reserve Account and each other Additional Debt Service Reserve Account (if any) (or, if the Senior Facilities Debt Service Reserve Account or any such Additional Debt Service Reserve Account is not yet required to be funded, the amount that will be required to be funded therein on the first date on which such account is required to be funded)) by (1) in the case of clause (x) above, by the Phase 1 LNG Facility Date Certain and (2) in the case of clause (y) above, by the Phase 2 LNG Facility Date Certain (such amount in this clause (ii), the “Required Completion Amount”);

(b) the Borrower reasonably believes that (x) the Project Phase 1 Completion Date shall occur by the Phase 1 LNG Facility Date Certain and (y) the Project Phase 2 Completion Date shall occur by the Phase 2 LNG Facility Date Certain.

2.3 the Borrower has delivered to the Intercreditor Agent a certification from the Independent Engineer confirming (a) that it reasonably expects (x) the Project Phase 1 Completion Date shall occur by the Phase 1 LNG Facility Date Certain and (y) the Project Phase 2 Completion Date shall occur by the Phase 2 LNG Facility Date Certain and (b) the Obligors are reasonably anticipated to have access to funds equal to or in excess of the Required Completion Amount.

Section 3. Representations and Warranties. Each of the Obligors hereby represents and warrants to the Lenders, Credit Facility Agent and Intercreditor Agent that:

3.1 upon the effectiveness of the amendments set forth in Section 1, no Unmatured Loan Facility Event of Default or Loan Facility Event of Default has occurred and is Continuing or will result from the consummation of the transactions contemplated by this Amendment; and

3.2 upon the effectiveness of the amendments set forth in Section 1, each of the representations and warranties of the Obligors in the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents is true and correct in all material respects except (A) for those representations and warranties that are qualified by materiality, which are true and correct in all respects on and as of the date hereof (or, if stated to have been made solely as of an earlier date, as of such earlier date) and (B) for the representations and warranties set forth in Section 5.1 (Initial Representations and Warranties of the Obligors) of the Common Terms Agreement, which were made only on the Upsize Closing Date.

Section 4. Finance Document. This Amendment constitutes a Finance Document as such term is defined in, and for purposes of, the Common Terms Agreement. Each of the parties hereto agree that each reference to “Common Terms Agreement” in each Finance Document, including the Intercreditor Agreement and Credit Facility Agreement, shall refer to the Common Terms Agreement as amended hereby.

Section 5. Governing Law. THIS AMENDMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA.

 

5


Section 6. Headings. All headings in this Amendment are included only for convenience and ease of reference and shall not be considered in the construction and interpretation of any provision hereof.

Section 7. Binding Nature and Benefit; Amendment. This Amendment shall be binding upon and inure to the benefit of each party hereto and their respective successors and permitted assigns. This Amendment may not be amended or modified except pursuant to a written instrument signed by all parties hereto.

Section 8. Counterparts. This Amendment may be executed in multiple counterparts, each of which shall be deemed an original for all purposes, but all of which together shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this Amendment by facsimile or portable document format (“pdf”) shall be effective as delivery of a manually executed counterpart of this Amendment.

Section 9. No Modifications; No Other Matters. Except as expressly provided for herein, the terms and conditions of the Common Terms Agreement, the Credit Facility Agreement and the other Finance Documents shall continue unchanged and shall remain in full force and effect. This Amendment shall apply solely in the specific instances and for the specific purposes expressly set forth herein and shall not be deemed or construed as a waiver of any other matters or to prejudice any rights which any of the Secured Parties may now have or may have in the future under or in connection with the Finance Documents or any of the instruments or documents referred to therein, nor shall this Amendment apply to any other matters.

Section 10. E-Signature. The words “execution,” “signed,” “signature,” and words of like import in this Amendment shall be deemed to include electronic signatures or electronic records, each of which shall be of the same legal effect, validity or enforceability as a manually executed signature or the use of a paper-based recordkeeping system, as the case may be, to the extent and as provided for in any legal requirements, including the Federal Electronic Signatures in Global and National Commerce Act, the New York State Electronic Signatures and Records Act, or any other similar state laws based on the Uniform Electronic Transactions Act.

Section 11. Direction to Credit Facility Agent and Intercreditor Agent.

11.1 By their signature below, each of the undersigned Credit Facility Lenders (collectively constituting the Required Lenders) instructs the Credit Facility Agent to (i) execute this Amendment and (ii) direct the Intercreditor Agent to execute this Amendment; and

11.2 Based on the instructions in Section 11.1, the Credit Facility Agent, constituting the Requisite Intercreditor Parties (as defined in the Intercreditor Agreement), hereby directs the Intercreditor Agent to execute this Amendment.

[Remainder of the page left intentionally blank.]

 

6


IN WITNESS WHEREOF, the Parties have caused this Amendment to be duly executed by their officers thereunto duly authorized as of the day and year first above written.

 

VENTURE GLOBAL PLAQUEMINES LNG,

LLC,

as the Borrower

By:   /s/ Jonathan W. Thayer
Name:   Jonathan W. Thayer
Title:   Chief Financial Officer

VENTURE GLOBAL GATOR EXPRESS, LLC,

as the Guarantor

By:   /s/ Jonathan W. Thayer
Name:   Jonathan W. Thayer
Title:   Chief Financial Officer

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set
forth above.
NATIXIS, NEW YORK BRANCH,
as Credit Facility Agent
By:   /s/ Katarina Janosikova
Name:   Katarina Janosikova
Title:   Director
By:   /s/ Frederic Bouley
Name:   Frederic Bouley
Title:   Director

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set
forth above.
ROYAL BANK OF CANADA,
as Intercreditor Agent
By:   /s/ Richard DSouza
Name:   Richard DSouza
Title:   Manager Agency Services

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

National Bank of Canada,

as Lender

By:   /s/ Andrew Nguyen
Name:   Andrew Nguyen
Title:   Authorized Signatory
By:   /s/ John Hunt
Name:   John Hunt
Title:   Authorized Signatory

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

[__],

as Lender

By:   /s/ Michael Pantelogianis
Name:   Michael Pantelogianis
Title:   Co-CEO
  Apterra Infrastructure Capital LLC

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

Goldman Sachs Bank USA,

as Lender

By:   /s/ Priyankush Goswami
Name:   Priyankush Goswami
Title:   Authorized Signatory

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set
forth above.
KfW. IPEX-Bank GmbH,
as Lender
By:   /s/ Philipp Meyer-Gohde
Name:   Philipp Meyer-Gohde
Title:   Vice President
By:   /s/ Erik Beste
Name:   Erik Beste
Title:   Associate

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

JPMORGAN CHASE BANK, N.A.,

as Lender

By:   /s/ Arina Mavilian
Name:   Arina Mavilian
Title:   Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

AOZORA BANK, LTD.,

as Lender

By:   /s/ Hirokazu Aoyama
Name:   Hirokazu Aoyama
Title:   Senior Vice President & Group Head

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

ACT JUNIPER A, L.P.,

as Lender

By: Apollo Clean Transition Capital Advisors,
L.P., its general partner
By: ACTC Advisors GP, LLC, its general partner
By:   /s/ William B. Kuesel
  Name:   William B. Kuesel
  Title:   Vice President

AIC HOLDINGS 2-Z,

as Lender

By: AIC Intermediate Holdings (DC), LLC, its general partner
By: Apollo Infrastructure Company LLC – Series
II, its sole member
By: Apollo Principal Holdings B, L.P., its sole member
By: Apollo Principal Holdings B GP, LLC, its general partner
By:   /s/ William B. Kuesel
  Name:   William B. Kuesel
  Title:   Vice President

APOLLO CREDIT MASTER FUND LTD.,

as Lender

By: Apollo ST Fund Management LLC, its investment manager
By:   /s/ William B. Kuesel
  Name:   William B. Kuesel
  Title:   Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


APOLLO CREDIT STRATEGIES ABSOLITE

RETURN AGGREGATOR A, L.P.,

as Lender

By: Apollo Defined Return Management, L.P., its investment manager
By: Apollo Defined Return Management GP,
LLC, its general partner
By:   /s/ William B. Kuesel
  Name:   William B. Kuesel
  Title:   Vice President
APOLLO PYTHIA FUND, L.P.,
as Lender
By: Apollo Delphi Management, L.P., its investment manager
By: Apollo Delphi Management GP, LLC, its general partner
By: Apollo Capital Management, L.P., its sole member
By: Apollo Capital Management GP, LLC, its general partner
By:   /s/ William B. Kuesel
  Name:   William B. Kuesel
  Title:   Vice President
APOLLO TR IMPACT AND SUSTAINABLE

CREDIT HOLDINGS LTD.,

as Lender

By: Apollo Total Return Master Fund LP, its shareholder
By: Apollo Total Return Management LLC, its investment manager
By:   /s/ William B. Kuesel
  Name:   William B. Kuesel
  Title:   Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


ATHORA LUX INVEST NL – CRE DIRECT

LENDING FUND,

as Lender

By: Apollo Management International LLP, its portfolio manager
By: Apollo International Management Holdings,
LLC, its member
By:   /s/ William B. Kuesel
  Name:   William B. Kuesel
  Title:   Vice President

APOLLO DIVERSIFIED CREDIT FUND,

as Lender

By: Apollo Capital Credit Adviser, LLC, its investment manager
By:   /s/ William B. Kuesel
  Name:   Kristin Hester
  Title:   Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.
MIZUHO BANK, LTD.,
As Lender
By:   /s/ Dominick D’Ascoli
Name:   Dominick D’Ascoli
Title:   Director

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.
Regions Bank,
as Lender
By:   /s/ Tedrick Tarver
Name:   Tedrick Tarver
Title:   Director

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.
Landesbank Baden-Wuerttemberg New York
Branch,
as Lender
By:   /s/ Arndt Bruns
Name:   Arndt Bruns
Title:   Director
By:   /s/ Andre Sorokin
Name:   Andre Sorokin
Title:   Associate

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set
forth above.
LANDESBANK HESSEN-THÜRINGEN
GIROZENTRALE, NEW YORK BRANCH,
as Lender
By:   /s/ Manuel Liebers
Name:   Manuel Liebers
Title:   Vice President
By:   /s/ Ralf Goebel
Name:   Ralf Goebel
Title:   Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.
BANK OF AMERICA, N.A.,
as Lender
By:   /s/ Ronald E. McKaig
Name:   Ronald E. McKaig
Title:   Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

[SPT Infrastructure Finance Sub-4 LLC],

as Lender

By:   /s/ Haig Najarian
Name:   Haig Najarian
Title:   Authorized Signatory

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

MUFG Bank Ltd.,

as Lender

By:   /s/ John Smith
Name:   John Smith
Title:   Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

CaixaBank S A,

as Lender

By:   /s/ Jesus Andese
Name:   Jesus Ansede
Title:  
By:   /s/ Maria Luisa Muñoz
Name:   Maria Luisa Muñoz
Title:  

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.
BANCO DE SABADELL, S.A., MIAMI

BRANCH,

as Lender

By:   /s/ Enrique Castillo
Name:   Enrique Castillo
Title:   Head of Corporate Banking

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.
THE BANK OF NOVA SCOTIA, HOUSTON

BRANCH,

as Lender

By:   /s/ Joe Lattanzi
Name:   Joe Lattanzi
Title:   Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

Truist Bank,

as Lender

By:   /s/ David Rhodes
Name:   David Rhodes
Title:   Director

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

BANK OF CHINA, NEW YORK BRANCH

as Lender

By:   /s/ Jinan Yan
Name:   Jinan Yan
Title:   Executive Vice President

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.
RAYMOND JAMES BANK,
as Lender
By:   /s/ Robert F. Moyle
Name:   Robert F. Moyle
Title:   Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA


Acknowledged and agreed as of the first date set forth above.

WELLS FARGO BANK, N.A.,

as Lender

By:   /s/ Nathan Starr
Name:   Nathan Starr
Title:   Managing Director

 

SIGNATURE PAGE TO AMENDMENT NO. 3 TO CTA

Exhibit 10.91

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

 

 

 

VENTURE GLOBAL LNG, INC.

AND EACH OF THE GUARANTORS PARTY HERETO FROM TIME TO TIME

8.125% SENIOR SECURED NOTES DUE 2028

8.375% SENIOR SECURED NOTES DUE 2031

 

 

INDENTURE

Dated as of May 26, 2023

 

 

The Bank of New York Mellon Trust Company, N.A.,

as Trustee and Collateral Agent

 

 

 

 

 


TABLE OF CONTENTS

ARTICLE 1

DEFINITIONS AND INCORPORATION BY REFERENCE

 

Section 1.01

 

Definitions

     1  

Section 1.02

 

Other Definitions

     48  

Section 1.03

 

Rules of Construction

     49  

Section 1.04

 

Limited Condition Transactions

     51  

Section 1.05

 

Certain Compliance Calculations

     52  

Section 1.06

 

Acts of Holders

     52  

Section 1.07

 

Timing of Payment

     54  

Section 1.08

 

Role of the Collateral Agent

     54  

ARTICLE 2

 

THE NOTES

 

 

Section 2.01

 

Form and Dating

     54  

Section 2.02

 

Execution and Authentication

     55  

Section 2.03

 

Registrar and Paying Agent

     56  

Section 2.04

 

Paying Agent to Hold Money in Trust

     56  

Section 2.05

 

Holder Lists

     57  

Section 2.06

 

Transfer and Exchange

     57  

Section 2.07

 

Replacement Notes

     70  

Section 2.08

 

Outstanding Notes

     70  

Section 2.09

 

Treasury Notes

     70  

Section 2.10

 

Temporary Notes

     71  

Section 2.11

 

Cancellation

     71  

Section 2.12

 

Defaulted Interest

     71  

ARTICLE 3

 

REDEMPTION AND PREPAYMENT

 

 

Section 3.01

 

Notices to Trustee

     71  

Section 3.02

 

Selection of Notes to Be Redeemed

     72  

Section 3.03

 

Notice of Redemption

     72  

Section 3.04

 

Effect of Notice of Redemption

     74  

Section 3.05

 

Deposit of Redemption Price

     74  

Section 3.06

 

Notes Redeemed or Purchased in Part

     74  

Section 3.07

 

Optional Redemption

     74  

Section 3.08

 

Mandatory Redemption; Purchases of Notes

     76  

Section 3.09

 

Offer to Purchase by Application of Excess Proceeds

     76  

 

i


ARTICLE 4

COVENANTS

 

Section 4.01

 

Payment of Notes

     79  

Section 4.02

 

Maintenance of Office or Agency

     79  

Section 4.03

 

Reports

     80  

Section 4.04

 

Compliance Certificate

     83  

Section 4.05

 

Taxes

     83  

Section 4.06

 

Stay, Extension and Usury Laws

     83  

Section 4.07

 

Limitation on Restricted Payments

     83  

Section 4.08

 

Limitation on Dividends and Other Payment Restrictions Affecting Restricted Subsidiaries

     89  

Section 4.09

 

Limitation on Indebtedness, Disqualified Stock and Preferred Equity

     92  

Section 4.10

 

Limitation on Sales of Assets

     98  

Section 4.11

 

Limitation on Transactions with Affiliates

     102  

Section 4.12

 

Limitation on Liens

     106  

Section 4.13

 

[Reserved]

     106  

Section 4.14

 

Corporate Existence

     106  

Section 4.15

 

Offer to Repurchase Upon Change of Control Triggering Event

     107  

Section 4.16

 

Future Guarantees

     108  

Section 4.17

 

Designation of Restricted and Unrestricted Subsidiaries

     109  

Section 4.18

 

Suspension of Certain Covenants

     109  

ARTICLE 5

 

SUCCESSORS

 

 

Section 5.01

 

Merger, Consolidation or Sale of Assets

     111  

Section 5.02

 

Successor Corporation Substituted

     113  

ARTICLE 6

 

DEFAULTS AND REMEDIES

 

 

Section 6.01

 

Events of Default

     114  

Section 6.02

 

Acceleration

     116  

Section 6.03

 

Other Remedies

     118  

Section 6.04

 

Waiver of Past Defaults

     118  

Section 6.05

 

Control by Majority

     119  

Section 6.06

 

Limitation on Suits

     119  

Section 6.07

 

Rights of Holders of Notes to Receive Payment

     120  

Section 6.08

 

Collection Suit by Trustee

     120  

Section 6.09

 

Trustee May File Proofs of Claim

     120  

Section 6.10

 

Priorities

     121  

Section 6.11

 

Undertaking for Costs

     121  

 

ii


ARTICLE 7

TRUSTEE

 

Section 7.01

  Duties of Trustee      121  

Section 7.02

  Rights of Trustee      122  

Section 7.03

  Individual Rights of Trustee      124  

Section 7.04

  Trustee’s Disclaimer      124  

Section 7.05

  Notice of Defaults      125  

Section 7.06

  Compensation and Indemnity      125  

Section 7.07

  Replacement of Trustee      126  

Section 7.08

  Successor Trustee by Merger, etc.      127  

Section 7.09

  Eligibility; Disqualification      127  

Section 7.10

  Security Documents      127  
ARTICLE 8

 

LEGAL DEFEASANCE AND COVENANT DEFEASANCE

 

Section 8.01

  Option to Effect Legal Defeasance or Covenant Defeasance      127  

Section 8.02

  Legal Defeasance and Discharge      128  

Section 8.03

  Covenant Defeasance      128  

Section 8.04

  Conditions to Legal or Covenant Defeasance      129  

Section 8.05

  Deposited Money and Government Securities to be Held in Trust; Other Miscellaneous Provisions      130  

Section 8.06

  Repayment to Issuer      131  

Section 8.07

  Reinstatement      131  
ARTICLE 9

 

AMENDMENT, SUPPLEMENT AND WAIVER

 

Section 9.01

  Without Consent of Holders of Notes      131  

Section 9.02

  With Consent of Holders of Notes      133  

Section 9.03

  Revocation and Effect of Consents      135  

Section 9.04

  Notation on or Exchange of Notes      135  

Section 9.05

  Trustee to Sign Amendments, etc.      135  

ARTICLE 10

 

GUARANTEES

 

 

Section 10.01

  Guarantee      136  

Section 10.02

  Limitation on Guarantor Liability      137  

Section 10.03

  Execution and Delivery of Guarantee      137  

Section 10.04

  Releases      137  

 

iii


ARTICLE 11

SATISFACTION AND DISCHARGE

 

Section 11.01  Satisfaction and Discharge

     139  

Section 11.02  Application of Trust Money

     140  

ARTICLE 12

 

COLLATERAL AND SECURITY

 

 

Section 12.01  General

     140  

Section 12.02  Security Documents

     140  

Section 12.03  Recording, Registration and Opinions; Trustee’s Disclaimer Regarding Collateral

     142  

Section 12.04  Possession, Use and Release of Collateral

     143  

Section 12.05  Suits to Protect the Collateral

     145  

Section 12.06  Authorization of Receipt of Funds by the Trustee Under the Security Documents

     145  

Section 12.07  Purchaser Protected

     145  

ARTICLE 13

 

MISCELLANEOUS

 

 

Section 13.01  Notices

     146  

Section 13.02  Certificate and Opinion as to Conditions Precedent

     147  

Section 13.03  Statements Required in Certificate or Opinion

     147  

Section 13.04  Rules by Trustee and Agents

     148  

Section 13.05  No Personal Liability of Directors, Managers, Officers, Members, Partners, Employees and Equityholders

     148  

Section 13.06  Governing Law; Waiver of Trial by Jury; Jurisdiction

     148  

Section 13.07  No Adverse Interpretation of Other Agreements

     149  

Section 13.08  Successors

     149  

Section 13.09  Severability

     149  

Section 13.10  Execution; Counterpart Originals

     149  

Section 13.11  Table of Contents, Headings, etc.

     149  

Section 13.12  Tax Matters

     150  

 

EXHIBITS

Exhibit A-1

  

FORM OF NOTE DUE 2028

Exhibit A-2

  

FORM OF NOTE DUE 2031

Exhibit B

  

FORM OF CERTIFICATE OF TRANSFER

Exhibit C

  

FORM OF CERTIFICATE OF EXCHANGE

 

iv


Exhibit D

  

FORM OF CERTIFICATE FROM ACQUIRING INSTITUTIONAL ACCREDITED INVESTOR

Exhibit E

  

FORM OF SUPPLEMENTAL INDENTURE

Exhibit F

  

FORM OF FIRST LIEN INTERCREDITOR AGREEMENT

Exhibit G

  

FORM OF JUNIOR LIEN INTERCREDITOR AGREEMENT

 

v


INDENTURE dated as of May 26, 2023 between Venture Global LNG, Inc., a Delaware corporation, and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent.

W I T N E S S E T H

WHEREAS, the Issuer has duly authorized the creation of (i) an issue of $2,000,000,000 aggregate principal amount of the Issuer’s 8.125% Senior Secured Notes due 2028 (the “Initial 2028 Notes”) and an additional $250,000,000 aggregate principal amount of the Issuer’s 8.125% Senior Secured Notes due 2028 (the “Initial Additional 2028 Notes”), and (ii) an issue of $2,000,000,000 aggregate principal amount of the Issuer’s 8.375% Senior Secured Notes due 2031 (the “Initial 2031 Notes”) and an additional $250,000,000 aggregate principal amount of the Issuer’s 8.375% Senior Secured Notes due 2031 (the “Initial Additional 2031 Notes”).

WHEREAS, the Issuer has duly authorized the execution and delivery of this Indenture (as defined herein).

NOW, THEREFORE, the Issuer, the Trustee and the Collateral Agent agree as follows for the benefit of each other and for the equal and ratable benefit of the Holders (as defined herein).

ARTICLE 1

DEFINITIONS AND INCORPORATION BY REFERENCE

Section 1.01 Definitions.

2028 Notes” means the Issuer’s 8.125% Senior Secured Notes due 2028.

2031 Notes” means the Issuer’s 8.375% Senior Secured Notes due 2031.

Acquired Debt” means Indebtedness (1) of a Person or any of its Subsidiaries existing at the time such Person becomes a Restricted Subsidiary, (2) assumed in connection with the acquisition of assets from such Person, in each case whether or not incurred by such Person in connection with or in contemplation of such Person becoming a Restricted Subsidiary of the Issuer or such acquisition, or (3) of a Person at the time such Person merges with or into or consolidates or otherwise combines with the Issuer or any Restricted Subsidiary. Acquired Debt will be deemed to have been incurred, with respect to clause (1) of the preceding sentence, on the date such Person becomes a Restricted Subsidiary, with respect to clause (2) of the preceding sentence, on the date of consummation of such acquisition of assets and, with respect to clause (3) of the preceding sentence, on the date of the relevant merger, consolidation or other combination.

Additional Notes” means (i) the Initial Additional 2028 Notes and the Initial Additional 2031 Notes, and (ii) other additional Notes (other than the Initial Notes) issued from time to time under this Indenture in accordance with Section 2.01, Section 2.02, Section 4.09 and Section 4.12 hereof.


Additional Agent” means the administrative agent and/or trustee (as applicable) or any other similar agent, representative or Person under any Secured Financing Document, in each case, together with its successors and permitted assigns in such capacity.

Additional First Lien Debt Facility” means one or more debt facilities, commercial paper facilities or indentures that are secured equally and ratably with the Notes by the Collateral and whose Senior Class Debt Representative has become a party to an Applicable Intercreditor Agreement in accordance therewith, in each case, as amended, amended and restated, supplemented or otherwise modified, refinanced or replaced from time to time; provided that this Indenture shall not constitute an Additional First Lien Debt Facility at any time.

Additional First Lien Documents” means, with respect to any series of Additional First Lien Obligations, the Notes, credit agreements, indentures, security documents and other operative agreements evidencing or governing such Indebtedness, and each other agreement entered into for the purpose of securing any series of Additional First Lien Obligations, as the same may be amended, restated, supplemented or otherwise modified from time to time.

Additional First Lien Obligations” means, with respect to any Additional First Lien Debt Facility, (a) all principal of and interest (including, without limitation, any interest that accrues after the commencement of any case, proceeding or other action relating to the bankruptcy, insolvency or reorganization of the Issuer or any Guarantor, whether or not allowed or allowable as a claim in any such proceeding) payable with respect to such Additional First Lien Debt Facility, (b) all other amounts payable to the related Additional First Lien Secured Parties under the related Additional First Lien Documents and (c) any renewals or extensions of the foregoing.

Additional First Lien Secured Parties” means, with respect to any series of Additional First Lien Obligations, the holders of such Additional First Lien Obligations, the Additional Agent with respect thereto, any trustee or agent or any other similar agent or Person therefor under any related Additional First Lien Documents and the beneficiaries of each indemnification obligation undertaken by the Issuer or any Guarantor under any related Additional First Lien Documents.

Affiliate” means, with respect to any specified Person, any other Person directly or indirectly controlling or controlled by or under direct or indirect common control with such specified Person.

For the purposes of this definition, “control,” when used with respect to any specified Person, means the power to direct or cause the direction of the management and policies of such Person, directly or indirectly, whether through the ownership of voting securities, by contract or otherwise; and the terms “controlling” and “controlled” have meanings correlative to the foregoing.

Agent” means the Collateral Agent, any Registrar, co-registrar, Paying Agent or additional paying agent in respect of the Notes.

Applicable Intercreditor Agreement” means, as the context may require, the First Lien Intercreditor Agreement and/or the Junior Lien Intercreditor Agreement, or any Market Intercreditor Agreement or another intercreditor agreement (which may, if applicable consist of a collateral proceeds “waterfall”).

 

2


applicable law” means, except as the context may otherwise require, all applicable laws (including common law), rules, regulations, ordinances, judgments, decrees, injunctions, writs and orders of any Governmental Authority.

Applicable Procedures” means, with respect to any transfer or exchange of or for, redemption of, or notice with respect to beneficial interests in any Global Note or the redemption or repurchase of any Global Note, the rules and procedures of DTC and/or the Depositary that apply to such transfer, exchange, redemption or repurchase.

Applicable Redemption Premium” means, with respect to any Note on any redemption date, the greater of:

(1) 1.0% of the principal amount of the Note; and

(2) the excess of:

(A) the present value at such redemption date of: (i) with respect to the 2028 Notes, (x) the redemption price of such Note at June 1, 2025 (such redemption price being set forth in the table appearing in Section 3.07(c)), plus (y) all required remaining scheduled interest payments due on such Note through June 1, 2025, and (ii) with respect to the 2031 Notes, (x) the redemption price of such Note at June 1, 2026 (such redemption price being set forth in the table appearing in Section 3.07(c)), plus (y) all required remaining scheduled interest payments due on such Note through June 1, 2026, in each case excluding accrued but unpaid interest to, but excluding, the redemption date and computed using a discount rate equal to the Treasury Rate as of such redemption date plus 50 basis points; over

(B) the outstanding principal amount of the Note,

as calculated by the Issuer or an agent appointed by the Issuer. For the avoidance of doubt, calculations of the Applicable Redemption Premium shall not be a duty or obligation of the Trustee, the Collateral Agent, the Registrar or any Paying Agent or any other Agent.

Asset Sale” means:

(1) the sale, lease, transfer, conveyance or other disposition of any assets by the Issuer or any of its Restricted Subsidiaries (including by way of a Sale and Leaseback Transaction) outside of the ordinary course of business; provided, however, that the sale, lease, transfer, conveyance or other disposition of all or substantially all of the assets of the Issuer and its Restricted Subsidiaries taken as a whole will be governed by Section 4.15 and/or Section 5.01 and not by Section 4.10; and

(2) the issuance of Equity Interests by any Restricted Subsidiary or the sale by the Issuer or any of its Restricted Subsidiaries of Equity Interests in any of the Restricted Subsidiaries (in each case, other than directors’ qualifying shares).

 

3


Notwithstanding the preceding, none of the following items will be deemed to be an Asset Sale:

(1) any single transaction or series of related transactions that involves assets having a Fair Market Value of less than the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period;

(2) a transfer of assets or Equity Interests between or among the Issuer and any Restricted Subsidiary, except to the extent such assets or Equity Interests constitutes or would constitute Collateral unless such assets or Equity Interests would continue to constitute Collateral following such transfer or would constitute Excluded Capital Stock following such transfer;

(3) an issuance of Equity Interests by a Restricted Subsidiary to the Issuer or to a Restricted Subsidiary;

(4) the sale, lease or other transfer of accounts receivable, inventory or other assets in the ordinary course of business, and any sale or other disposition of damaged, worn-out, surplus or obsolete assets or assets that are no longer useful in the conduct of the business of the Issuer and its Restricted Subsidiaries or economically practicable or commercially reasonable to maintain, in each case whether now owned or hereafter acquired, in each case in in the good faith determination of the Issuer;

(5) the sale, conveyance or other disposition for value of environmental attributes or energy, fuel, water or emission credits or similar rights or contracts for any of the foregoing by the Issuer or any of its Restricted Subsidiaries;

(6) licenses and sublicenses by the Issuer or any of its Restricted Subsidiaries;

(7) any surrender or waiver of contract rights or settlement, release, recovery on or surrender of contract, tort or other claims;

(8) the granting and enforcement and exercise of a Lien not prohibited by Section 4.12, and any sale, transfer or other disposition in connection therewith or deemed reasonably necessary or desirable by the Issuer in good faith for the consummation thereof;

(9) any Restricted Payment not prohibited by Section 4.07 or the proceeds of which are substantially contemporaneously used to fund a Permitted Investment or the making of a Restricted Payment not prohibited by Section 4.07, or any Permitted Investment;

(10) the sale or other disposition of cash or Cash Equivalents;

(11) the disposition of receivables in connection with the compromise, settlement or collection thereof in bankruptcy or similar proceedings;

(12) the foreclosure, condemnation, expropriation, forced dispositions, eminent domain or any similar action with respect to any property or other assets, transfers of any property that have been subject to a casualty to the respective insurer of such property as part of an insurance settlement or upon receipt of the net proceeds of such casualty event, or a surrender or waiver of contract rights or the settlement, release or surrender of contract, tort or other claims of any kind;

 

4


(13) the disposition of assets to a person who is providing services (the provision of which has been or is to be outsourced by the Issuer or any Subsidiary to such person) related to such assets;

(14) the lease (including Sale and Leaseback Transactions and inverted lease transactions), as lessor or sublessor, or license (other than any long-term exclusive license), as licensor or sublicensor, of real or personal property or intellectual property that does not materially interfere with the business of the Issuer and its Restricted Subsidiaries, taken as a whole;

(15) Sale and Leaseback Transactions, as lessee or sublessee, and other dispositions by a Non-Recourse Subsidiary in connection with Non-Recourse Financing incurred by such Non-Recourse Subsidiary;

(16) the cancellation of intercompany Indebtedness with the Issuer or any of its Restricted Subsidiaries permitted under this Indenture;

(17) swaps of assets for other similar assets or assets whose value is reasonably equivalent or greater in terms of type, value and quality, than the assets being swapped, as determined in good faith by the Issuer;

(18) the unwinding or termination of Hedging Obligations;

(19) the issuance, sale or other disposition of Equity Interests in (i) Joint Ventures or (ii) Subsidiaries, substantially all of which Subsidiaries’ or Joint Ventures’ assets are assets that, if disposed of separately, would not constitute an Asset Sale, in a single transaction or series of related transactions;

(20) dispositions of investments in Joint Ventures to the extent required by, or made pursuant to buy/sell and/or put/call arrangements between the Joint Venture parties set forth in, Joint Venture agreements and similar binding arrangements;

(21) the issuance of Equity Interests by the Issuer or a Restricted Subsidiary to the holders of its Equity Interests in accordance with the charter, partnership agreement, limited liability company agreement or other governing documents of such Person;

(22) the issuance, sale or other disposition of Equity Interests or other assets of a Non-Recourse Subsidiary; provided that any Net Proceeds of such disposition are (A) applied to Project Costs of the Project to which such Non-Recourse Subsidiary relates or to repay a Non-Recourse Financing of such Project or (B) applied in accordance with clause (1) of Section 4.10(b);

(23) any sale, lease, conveyance or other disposition of Equity Interests in, or Indebtedness or other securities of, an Unrestricted Subsidiary;

 

5


(24) dispositions of improvements made to leased real property to landlords pursuant to customary terms of leases entered into in the ordinary course of business;

(25) the lapse or abandonment of intellectual property rights (including any registrations or applications therefor) in the ordinary course of business or consistent with industry practice, which in the reasonable good faith determination of the Issuer, are not material to the conduct of the business of the Issuer and its Subsidiaries, taken as a whole;

(26) any sale, transfer or other disposition to effect the formation of any Subsidiary that is a Delaware Divided LLC; provided that upon formation of such Delaware Divided LLC, such Delaware Divided LLC shall be a Restricted Subsidiary;

(27) any sale, transfer or other disposition in connection with, and deemed reasonably necessary or desirable by the Issuer in good faith for the consummation of, any IPO Reorganization Transactions or any Tax Restructuring;

(28) Permitted Intercompany Activities and related transactions;

(29) any Equity Financing Transaction;

(30) ECR Transactions; and

(31) (A) dispositions or discounts without recourse of accounts receivable, notes receivable, rights to payment, other current assets or participations therein, or (B) dispositions of assets in connection with any Permitted Receivables Financing Assets pursuant to any Permitted Receivables Financing (including Equity Interests in any Subsidiary all of substantially all of the assets of which are Permitted Receivables Financing Assets).

In the event that a transaction (or a portion thereof) meets the criteria of a permitted Asset Sale and would also be a permitted Restricted Payment or Permitted Investment, the Issuer, in its sole discretion, will be entitled to divide and classify such transaction (or a portion thereof) as an Asset Sale and/or one or more of the types of permitted Restricted Payments or Permitted Investments.

Asset Sale Prepayment Percentage” means 100%; provided that if, at the time of receipt by the Issuer or the relevant Restricted Subsidiary of the Net Proceeds from any Asset Sale (or at any time during the applicable reinvestment period described herein), on a pro forma basis after giving effect to the applicable Asset Sale and the application of the Net Proceeds therefrom, (i) the Holdco Debt Ratio is less than or equal to 0.95 to 1.00 and greater than 0.70 to 1.00, such percentage shall instead be 50% or (ii) the Holdco Debt Ratio is less than or equal to 0.70 to 1.00, such percentage shall instead be 0%.

Bank Product Obligations” means all obligations and liabilities of any kind, nature or character (whether direct or indirect, absolute or contingent, liquidated or unliquidated, voluntary or involuntary, due or to become due that are in existence on the Issue Date or thereafter incurred) of the Issuer or any Restricted Subsidiary, whether on account of principal, interest, reimbursement obligations, fees, indemnities, costs, expenses or otherwise, which may arise under, out of, or in

 

6


connection with any treasury, investment, depository, clearing house, wire transfer, commercial credit card, purchasing card, merchant card, cash management or automated clearing house transfers of funds services or any related services, including all renewals, extensions and modifications thereof and all costs, attorneys’ fees and expenses incurred by a holder of Bank Product Obligations in connection with the collection or enforcement thereof.

Bankruptcy Code” means Title 11 of the United States Code (11 U.S.C. § 101 et seq.), as amended.

Bankruptcy Law” means the Bankruptcy Code and any other state or federal insolvency, reorganization, moratorium or similar law for the relief of debtors.

Beneficial Owner” has the meaning assigned to such term in Rule 13d-3 and Rule 13d-5 under the Exchange Act. The terms “Beneficially Owns,” “Beneficially Owned” and “Beneficial Ownership” have a corresponding meaning.

Board of Directors” means:

(1) with respect to a corporation, the board of directors of the corporation (including any committee thereof duly authorized to act on behalf of such board);

(2) with respect to a partnership having only one general partner, the board of directors of the general partner of the partnership;

(3) with respect to a limited liability company, the managing member or members or any controlling committee of managing members or other governing body thereof; and

(4) with respect to any other Person, the board or committee of such Person serving a similar function.

Business Day” means a day other than a Saturday, Sunday or other day on which banking institutions in New York or a place of payment under this Indenture are authorized or required by law to close.

Capital Stock” means:

(1) in the case of a corporation or company, corporate stock or shares;

(2) in the case of an association or business entity, any and all shares, interests, participations, rights or other equivalents (however designated) of corporate stock;

(3) in the case of a partnership or limited liability company, partnership interests (whether general or limited) or membership interests; and

(4) any other interest or participation that confers on a Person the right to receive a share of the profits and losses of, or distributions of assets of, the issuing Person, but excluding from all of the foregoing any debt securities convertible into Capital Stock, whether or not such debt securities include any right of participation with Capital Stock.

 

7


Captive Insurance Subsidiary” means (a) any Subsidiary of the Issuer operating for the purpose of (i) insuring the businesses, operations or properties owned or operated by any Parent Entity, the Issuer or any of its Subsidiaries, including their future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members), and related benefits and/or (ii) conducting any activities or business incidental thereto (it being understood and agreed that activities which are relevant or appropriate to qualify as an insurance company for U.S. federal or state tax purposes shall be considered “activities or business incidental thereto”) or (b) any Subsidiary of any such insurance subsidiary operating for the same purpose described in clause (a) above.

Cash Equivalents” means, as at any date of determination, any of the following: (i) marketable securities (a) issued or directly and unconditionally guaranteed as to interest and principal by the United States government or (b) issued by any agency of the United States the obligations of which are backed by the full faith and credit of the United States, in each case maturing within one year after such date; (ii) marketable direct obligations issued by any state of the United States of America or any political subdivision of any such state or any public instrumentality thereof, in each case maturing within one year after such date and having, at the time of the acquisition thereof, a rating of at least A-1 from S&P or at least P-1 from Moody’s; (iii) commercial paper maturing no more than three months from the date of creation thereof and having, at the time of the acquisition thereof, a rating of at least A-1 from S&P or at least P-1 from Moody’s; (iv) certificates of deposit or bankers’ acceptances maturing within three months after such date and issued or accepted by any lender or by any commercial bank organized under the laws of the United States of America or any state thereof or the District of Columbia that (a) is at least “adequately capitalized” (as defined in the regulations of its primary Federal banking regulator) and (b) has Tier 1 capital (as defined in such regulations) of not less than $1,000,000,000; and (v) shares of any money market mutual fund that (a) has substantially all of its assets invested continuously in the types of investments referred to in clauses (i) and (ii) above, (b) has net assets of not less than $5,000,000,000, and (c) has the highest rating obtainable from either S&P or Moody’s.

Change of Control” means the occurrence of any of the following:

(1) the consummation of any transaction (including, without limitation, any merger or consolidation) the result of which is that any “person” or “group” of related persons (as such terms are used in Section 13(d)(3) of the Exchange Act) other than any of the Permitted Holders, becomes the beneficial owner (as such term is defined in Rules 13d- 3 and Rule 13d-5 under the Exchange Act), directly or indirectly, of more than 50% of the voting power of the Voting Stock of the Issuer (or its successors by merger, consolidation or purchase of all or substantially all of its assets); or

(2) the direct or indirect sale, lease, transfer, conveyance or other disposition (other than by way of merger or consolidation), in one or a series of related transactions, of all or substantially all of the properties or assets of the Issuer and its Subsidiaries taken as a whole to any “person” (as such term is used in Section 13(d)(3) of the Exchange Act) other than any of the Permitted Holders;

 

8


provided, however, that a transaction in which the Issuer becomes a Subsidiary of another Person (other than any of the Permitted Holders) shall not constitute a Change of Control if (a) the shareholders of the Issuer immediately prior to such transaction Beneficially Own, directly or indirectly through one or more intermediaries, at least a majority of the voting power of the outstanding Voting Stock of the Issuer immediately following the consummation of such transaction or (b) immediately following the consummation of such transaction, no “person” (as such term is defined above), other than such other Person (but including the holders of the Equity Interests of such other Person) and/or any of the Permitted Holders, “Beneficially Owns, directly or indirectly through one or more intermediaries, more than 50% of the voting power of the outstanding Voting Stock of the Issuer; provided further, (i) a Person or group shall not be deemed to Beneficially Own Voting Stock subject to an equity or asset purchase agreement, merger agreement, option agreement, warrant agreement or similar agreement (or voting or option or similar agreement related thereto) until the consummation of the acquisition of Voting Stock in connection with the transactions contemplated by such agreement, (ii) the phrase “person” or “group” is within the meaning of Section 13(d) or 14(d) of the Exchange Act, but excluding (A) any employee benefit plan of such Person or “group” and its subsidiaries and any Person acting in its capacity as trustee, agent or other fiduciary or administrator of any such plan and (B) any underwriter in connection with an IPO, and (iii) if any group includes one or more Permitted Holders, the issued and outstanding Voting Stock of the Issuer or the IPO Entity Beneficially Owned, directly or indirectly, by any Permitted Holders that are part of such group shall not be treated as being Beneficially Owned by such “group” or any other member of such group for purposes of determining whether a Change of Control has occurred.

Change of Control Triggering Event” means, with respect to a series of Notes, the occurrence of both a Change of Control and a Rating Decline with respect to such series of Notes.

Clearstream” means Clearstream Banking, S.A.

Code” means the United States Internal Revenue Code of 1986, as amended from time to time, and any successor statute thereto.

Collateral” means, unless released in accordance with the terms of this Indenture or the Collateral Agency Agreement and subject to the occurrence of any Reversion Date, all assets and properties subject to Liens created pursuant to the Security Documents to secure the Note Obligations (other than any Excluded Asset and any cash or cash equivalents (i) collateralizing letters of credit obligations under, or (ii) deposited in a debt service reserve account relating to, in each case, other series of First Lien Obligations).

Collateral Agency Agreement” means the Collateral Agency Agreement to be entered into on the Issue Date among the Issuer, each other Grantor (as defined and referred to therein), the Trustee and the Collateral Agent, as it may be amended, amended and restated, supplemented or otherwise modified from time to time.

 

9


Collateral Agent” has the meaning ascribed to such term in the Collateral Agency Agreement.

Commission” means the U.S. Securities and Exchange Commission.

continuing” means, with respect to any Default or Event of Default, that such Default or Event of Default has not been cured or waived.

Contractual Obligation” means as to any Person, any provision of any security issued by such Person or any obligation under any contract, agreement, instrument or other written undertaking to which such Person is a party or by which it or any of its property is bound.

Controlled Investment Affiliate” means, as to any Person, any other Person, which directly or indirectly is in control of, is controlled by, or is under common control with such Person and is organized by such Person (or any Person controlling such Person) primarily for making direct or indirect equity or debt investments in the Issuer and/or other companies.

Corporate Trust Office of the Trustee” means the address of the Trustee at 240 Greenwich Street-7E, New York, NY 10286 or such other address as to which the Trustee may give notice to the Issuer.

Credit Facilities” means one or more debt facilities, credit agreements, commercial paper facilities, note purchase agreements, indentures, or other agreements, in each case with banks, lenders, purchasers, investors, trustees, agents or other representatives of any of the foregoing, providing for revolving credit loans, term loans, receivables financing (including through the sale of receivables or interests in receivables to such lenders or other Persons or to special purpose entities formed to borrow from such lenders or other Persons against such receivables or sell such receivables or interests in receivables), or letters of credit, notes, earn-out obligations constituting Indebtedness or other borrowings or other extensions of credit, including any notes, mortgages, guarantees, collateral documents, instruments and agreements executed in connection therewith, in each case, as amended, restated, modified, renewed, refunded, restated, restructured, increased, supplemented, replaced or refinanced in whole or in part from time to time, including any replacement, refunding or refinancing facility or agreement that increases the amount permitted to be borrowed thereunder or alters the maturity thereof or adds entities as additional borrowers or guarantors thereunder and whether by the same or any other agent, lender group of lenders, counterparties or otherwise.

Cumulative Distributable Cash” means, with respect to any date of determination, the cumulative Distributable Cash for the period (taken as one accounting period) from, and including, the first day of the fiscal quarter in which the Issue Date occurs, to, and including, the end of the most recently ended fiscal quarter of the Issuer for which internal financial statements are available as of such date of determination.

Custodian” means the Trustee, as custodian with respect to the Global Notes, or any successor entity thereto.

Default” means any event that is, or with the passage of time or the giving of notice or both would be, an Event of Default.

 

10


Definitive Note” means a certificated Note registered in the name of the Holder thereof, issued in accordance with Section 2.06, substantially in the form of Exhibit A-1 and Exhibit A-2 except that such Note shall not bear the Global Note Legend and shall not have the “Schedule of Exchanges of Interests in the Global Note” attached thereto.

Delaware Divided LLC” means any Delaware LLC formed upon the consummation of a Delaware LLC Division.

Delaware LLC” means any limited liability company organized or formed under the laws of the State of Delaware.

Delaware LLC Division” means the statutory division of any Delaware LLC into two or more Delaware LLCs pursuant to Section 18-217 of the Delaware Limited Liability Company Act.

Derivative Instruments” with respect to a Person, means any contract, instrument or other right to receive payment or delivery of cash or other assets to which such Person or any Affiliate of such Person that is acting in concert with such Person in connection with such Person’s investment in the Notes (other than a Screened Affiliate) is a party (whether or not requiring further performance by such Person), the value and/or cash flows of which (or any material portion thereof) are materially affected by the value and/or performance of the Notes and/or the creditworthiness of the Issuer.

Depositary” means, with respect to the Notes issuable or issued in whole or in part in global form, any Person specified in Section 2.03 hereof as the Depositary with respect to the Notes, and any and all successors thereto appointed as Depositary hereunder and having become such pursuant to the applicable provision of this Indenture.

Designated Non-cash Consideration” means the fair market value of non-cash consideration received by the Issuer or a Restricted Subsidiary in connection with an Asset Sale that is so designated as Designated Non-cash Consideration pursuant to an Officer’s Certificate, setting forth the basis of such valuation, executed by the principal financial officer of the Issuer, less the amount of cash or Cash Equivalents received in connection with a subsequent sale of or collection on such Designated Non-cash Consideration. A particular item of Designated Non-Cash Consideration will no longer be considered to be outstanding when and to the extent it has been paid, redeemed or otherwise retired or sold or otherwise disposed of in exchange for consideration in the form of Cash Equivalents in compliance with Section 4.10.

Designated Preferred Stock” means Preferred Stock of the Issuer or any Parent Entity (in each case other than Disqualified Stock) that is issued for cash (other than to a Restricted Subsidiary or an employee stock ownership plan or trust established by the Issuer or any of its Subsidiaries) and is so designated as Designated Preferred Stock, pursuant to an Officer’s Certificate, on the issuance date thereof, the cash proceeds of which are excluded from any calculation of Incremental Funds.

Disqualified Stock” means, with respect to any Person, any Capital Stock of such Person that, by its terms (or by the terms of any security into which it is convertible or for which it is puttable or exchangeable, either mandatorily or at the option of the holder thereof), or upon the happening of any event or condition matures or is mandatorily redeemable (other than solely for

 

11


Capital Stock of such Person or any Parent Entity thereof that would not otherwise constitute Disqualified Stock, and for cash in lieu of fractional shares of Capital Stock and other than solely as a result of a change of control, asset sale, casualty, condemnation or eminent domain) pursuant to a sinking fund obligation or otherwise, or is redeemable at the option of the holder thereof (other than solely for Capital Stock of such Person or as a result of a change of control, asset sale, casualty, condemnation or eminent domain), in whole or in part, in each case prior to the date 91 days after the earlier of the maturity date of the Notes of the applicable series or the date the Notes of the applicable series are no longer outstanding; provided, however, that if such Capital Stock is issued to any future, current or former employee, director, officer, manager or consultant (or their respective Controlled Investment Affiliates or Immediate Family Members), of the Issuer, any of its Subsidiaries, any Parent Entity or any other entity in which the Issuer or a Restricted Subsidiary has an Investment and is designated in good faith as an “affiliate” by the Board of Directors of the Issuer (or the compensation committee thereof) or any other plan for the benefit of current, former or future employees (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or its Subsidiaries or by any such plan to such employees (or their respective Controlled Investment Affiliates or Immediate Family Members), such Capital Stock shall not constitute Disqualified Stock solely because it may be required to be repurchased by the Issuer or its Subsidiaries in order to satisfy applicable statutory or regulatory obligations.

Distributable Cash” means, for any period, the aggregate amount of net cash provided by (used in) operating activities of the Issuer and its Subsidiaries for such period, determined on a consolidated basis in accordance with GAAP, adjusted as follows (in each case, without duplication):

 

  (a)

decreased by the aggregate amount of net cash provided by (used in) operating activities of any Unrestricted Subsidiaries of the Issuer for such period; and

 

  (b)

increased by the sum of the following:

 

  (i)

the aggregate amount of any scheduled cash interest payments and any other debt service payments with respect to any Indebtedness of the Issuer and its Restricted Subsidiaries, solely to the extent such payments are actually made during such period using net cash provided by financing activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (ii)

the aggregate amount of any Test Revenue to the extent included in net cash provided by (used in) investing activities of the Issuer and its Restricted Subsidiaries for such period, determined on a consolidated basis in accordance with GAAP; plus

 

  (iii)

the aggregate amount of dividends, distributions or return on investment actually received by the Issuer or any of its Restricted Subsidiaries during such period in the form of cash or Cash Equivalents from any Person that is not a Restricted Subsidiary (including any Unrestricted Subsidiary, Joint Venture or investment recorded in such Person under the equity method of accounting); plus

 

12


  (iv)

solely to the extent Distributable Cash is used to determine the Fixed Charge Coverage Ratio, the aggregate amount of any operating expenses incurred by the Issuer during such period; and

 

  (c)

decreased by the sum of the following:

 

  (i)

the aggregate amount of any scheduled cash interest payments, amortization payments and any other debt service payments and repayments with respect to any Non-Recourse Financing of any Non-Recourse Subsidiary, solely to the extent such payments are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (ii)

the aggregate amount of any cash distributions or cash repurchase amounts actually paid during such period to any Person (other than the Issuer and its Restricted Subsidiaries) with respect to any Disqualified Stock or Preferred Equity issued by, or non-controlling interest in, any Non-Recourse Subsidiary, solely to the extent such distributions or repurchases are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (iii)

the aggregate amount of any mandatory payments actually made during such period with respect to any ECR Transaction, solely to the extent such payments are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (iv)

the aggregate amount of any Investments actually made by the Issuer or any of its Restricted Subsidiaries during such period in the form of cash or Cash Equivalents in any Person that is not a Restricted Subsidiary (including any Unrestricted Subsidiary, Joint Venture or Investment recorded in such Person under the equity method of accounting), solely to the extent such Investments are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; and

 

  (d)

decreased by deposits into (or increased by withdrawals from) any restricted cash accounts during such period that are required pursuant to any Non-Recourse Financing of any Non-Recourse Subsidiary (including fully funding any contingency requirements, reserving for remaining construction costs and fulfilling any debt service reserve account obligations), solely to the extent that such deposits (or withdrawals) decrease (or increase) net cash provided by (used in) operating activities of the Issuer and its Restricted Subsidiaries for such period.

Early Cargo Revenues” means, with respect to any group of Project Companies for an applicable Project, the total cash permitted to be distributed by such group of Project Companies to the Issuer prior to the applicable commercial operation date under the Non-Recourse Financing for the applicable Project.

 

13


ECR Transaction” means any transaction involving the use of Early Cargo Revenues (and no other funds of a Recourse Person) to provide credit support (contingent or otherwise), equitize or otherwise finance any Project Company in connection with a Non-Recourse Financing or Equity Financing Transaction; provided that, no Person that benefits from such ECR Transaction shall have recourse to any Recourse Person other than rights to Early Cargo Revenues actually received by any Recourse Person and (for the avoidance of doubt) shall not be entitled to any Lien on the assets of any Recourse Person.

Electronic Means” means any of the following communications methods: e-mail, facsimile transmission, secure electronic transmission containing applicable authorization codes, passwords and/or authentication keys issued by the Trustee, or another method or system specified by the Trustee as available for use in connection with its services hereunder.

Equity Financing Transaction” means any bona fide equity issuance or equity financing transaction or series of related transactions by any Non-Recourse Subsidiary (including, for the avoidance of doubt, any issuance or series of related issuances of Disqualified Stock, Preferred Equity or other Equity Interests by any Non-Recourse Subsidiary) (a) the proceeds of which are used for the financing (or refinancing) of all or any portion of any Project to which such Non- Recourse Subsidiary relates, all or any portion of any other Project Costs relating to any such Project, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith; provided that, to the extent such Disqualified Stock, Preferred Equity of other Equity Interests are issued by a Non-Recourse Subsidiary that is an obligor under any Non-Recourse Financing relating to the applicable Project, the proceeds of the issuance of such Disqualified Stock, Preferred Equity of other Equity Interests may be used for the purpose of, or in connection with, any financing (or refinancing) of all or any portion of any one or more other Projects, all or any portion of any Project Costs relating to any such one or more other Projects, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith, so long as such use of proceeds is permitted under the terms of each Non-Recourse Financing that is then outstanding to which such Non-Recourse Subsidiary is a party (and not pursuant to an amendment or waiver of any such Non-Recourse Financing in contemplation thereof); and (b) such transaction or series of related transactions does not result in such Non-Recourse Subsidiary no longer constituting a “Restricted Subsidiary” for purposes of this Indenture immediately after giving effect thereto.

Equity Interests” means Capital Stock and all warrants, options or other rights to acquire Capital Stock (but excluding any debt security that is convertible into, or exchangeable for, Capital Stock).

Equity Offerings” means any public or private sale after the Issue Date of Capital Stock of the Issuer or any Parent Entity (including an IPO), the proceeds of which have been contributed to the Issuer as common equity, other than (i) public offerings with respect to the Issuer’s common stock registered on Form S-4 or Form S-8; and (ii) issuances to the Issuer or any Subsidiary of the Issuer.

Euroclear” means Euroclear Bank, S.A./N.V.

 

14


Exchange Act” means the U.S. Securities Exchange Act of 1934, as amended, or any successor statute, and the rules and regulations promulgated by the Commission thereunder.

Excluded Assets” means (a) any asset (including any general intangibles and any contract, instrument, lease, license, permit, agreement or other document, or any property or other right subject thereto (including pursuant to a purchase money security interest, capital lease or similar arrangement or, in the case of after-acquired property, pre-existing secured Indebtedness not incurred in anticipation of the acquisition by the Issuer or any Guarantor of such property)) the grant or perfection of a security interest in which would (i) constitute a violation of a restriction in favor of a third party (other than the Issuer, any Guarantor or any Subsidiary thereof) or result in the abandonment, invalidation or unenforceability of any right or assets of the Issuer or the relevant Guarantor, as applicable, (ii) result in a breach, termination (or a right of termination) or default under any such contract, instrument, lease, license, permit, agreement or other document (including pursuant to any “change of control” or similar provision) (there being no requirement pursuant to any Note Document to obtain any consent in respect thereof from any Person that is not also the Issuer, a Guarantor or any Subsidiary thereof) or (iii) permit any Person (other than the Issuer, any Guarantor or any Subsidiary thereof) to amend any rights, benefits and/or obligations of the Issuer or the relevant Guarantor, as applicable, in respect of such relevant asset or permit such Person to require the Issuer, any Guarantor or any Subsidiary thereof to take any action materially adverse to the interests of such Subsidiary, the Issuer or Guarantor; provided, however, that any such asset will only constitute an Excluded Asset under clause (i) or clause (ii) above to the extent such violation or breach, termination (or right of termination) or default would not be rendered ineffective pursuant to Sections 9-406, 9-407, 9-408 or 9-409 of the UCC (or any successor provision or provisions) of any relevant jurisdiction or any other applicable requirement of law; provided, further, that any such asset shall cease to constitute an Excluded Asset at such time as the condition causing such violation, breach, termination (or right of termination) or default or right to amend or require other actions no longer exists and to the extent severable, the security interest granted under the applicable Security Document shall attach immediately to any portion of such general intangible or other right that does not result in any of the consequences specified in clauses (i) through (iii) above, (b) Excluded Capital Stock, (c) any intent-to-use (or similar) trademark application prior to the filing of a “Statement of Use,” “Amendment to Allege Use” or similar filing with respect thereto, only to the extent, if any, that, and solely during the period, in which, if any, the grant of a security interest therein may impair the validity or enforceability, or result in the voiding of, such intent-to-use trademark application or any registration issuing therefrom under applicable law, (d) any asset or property (including Capital Stock), the grant or perfection of a security interest in which would (A) require any governmental or regulatory consent, approval, license or authorization (there being no requirement under any Note Document to obtain the consent of any Governmental Authority or other Person (other than the Issuer, any Guarantor or any Subsidiary thereof), including, without limitation, no requirement to comply with the Federal Assignment of Claims Act or any similar statute), unless such consent, approval, license or authorization has been obtained, (B) be prohibited or restricted by applicable requirements of law (including enforceable anti-assignment provisions of applicable requirements of law), except, in the case of the foregoing clause (A) and this clause (B), to the extent such prohibition would be rendered ineffective under applicable anti-assignment provisions of the UCC of any relevant jurisdiction notwithstanding such prohibition, (C) trigger termination of any contract pursuant to a “change of control” or similar provision and is binding on such asset on the Issue Date or at the time of its acquisition and not incurred in contemplation thereof; it being understood that

 

15


“Excluded Assets” shall not include proceeds or receivables arising out of any contract described in this clause (d) to the extent that the assignment of such proceeds or receivables is expressly deemed to be effective under the UCC or any other applicable law notwithstanding the relevant provision or (D) result in material adverse tax consequences to the Issuer, any Guarantor or any Subsidiary thereof, as determined by the Issuer in good faith, (e) (i) except to the extent a security interest therein can be perfected by the filing of a UCC financing statement, any leasehold interest and (ii) any real property or real property interest, (f) any margin stock, (g) any governmental or regulatory license or state or local franchise, charter, consent, permit or authorization to the extent the granting of a security interest therein is prohibited or restricted thereby or by applicable requirements of law, other than the proceeds thereof, the assignment of which is expressly deemed effective under the UCC notwithstanding such prohibition; provided, however, that any such asset will only constitute an Excluded Asset under this clause (g) to the extent such prohibition or restriction would not be rendered ineffective pursuant to applicable anti-assignment provisions of the UCC of any relevant jurisdiction, (h) any letter of credit right (other than to the extent a security interest in such letter of credit right can be perfected by filing an “all-assets” UCC financing statement) and all commercial tort claims, (i) any cash or Cash Equivalents (other than cash and Cash Equivalent representing identifiable proceeds of other Collateral, a security interest in which can be perfected through the filing of an “all-assets” UCC financing statement), (j) any deposit account or commodity or securities account (excluding any securities entitlements and any related assets to the extent a security interest therein can be perfected through the filing of an “all assets” UCC financing statement; it being understood that this exception does not apply to cash or Cash Equivalents other than cash and Cash Equivalents representing identifiable proceeds of other Collateral), (k) any motor vehicle, airplane or other asset subject to a certificate of title (other than to the extent a security interest therein can be perfected by filing an “all assets” UCC financing statement and without the requirement to list any VIN, serial or similar number), (l) any asset with respect to which the Collateral Agent and the Issuer or the relevant Guarantor, as applicable, have reasonably determined that the cost, burden, difficulty or consequence (including any effect on the ability of the Issuer or the relevant Guarantor, as applicable, to conduct its operations and business in the ordinary course of business) of obtaining or perfecting a security interest therein outweighs the benefit of a security interest to the relevant Notes Parties afforded thereby and (m) except for the Issuer, all assets and property of any other Person other than Pledged Equity and the proceeds thereof.

Excluded Capital Stock” means the Capital Stock of any Subsidiary of the Issuer that is (i) not a Wholly-Owned Subsidiary directly owned by the Issuer or any Guarantor, (ii) an Immaterial Subsidiary or (iii) an Unrestricted Subsidiary.

Existing Indebtedness” means any Indebtedness, Disqualified Stock and Preferred Stock of the Issuer and its Restricted Subsidiaries (other than the Notes, the Guarantees and Indebtedness that constitutes Non-Recourse Financing that is incurred by a Non-Recourse Subsidiary) outstanding on the Issue Date.

Fair Market Value” means the value that would be paid by a willing buyer to an unaffiliated willing seller in a transaction not involving distress of either party, as determined by the Issuer in good faith.

 

16


Finance Lease Obligations” means an obligation that is required to be classified and accounted for as a finance lease for financial reporting purposes on the basis of GAAP. The amount of such obligation will be the capitalized amount of such obligation at the time any determination thereof is to be made as determined on the basis of GAAP.

First Lien Obligations” means the Note Obligations and any Additional First Lien Obligations.

First Lien Secured Parties” means (i) the Collateral Agent, (ii) the Notes Parties and (iii) the Additional First Lien Secured Parties with respect to each series of Additional First Lien Obligations.

Fixed Charge Coverage Ratio” means as of any date of determination, the ratio of: (x) the aggregate amount of Distributable Cash for the applicable Test Period plus the aggregate amount of Fixed Charges for the applicable Test Period to (y) the aggregate amount of the Fixed Charges for the applicable Test Period. In the event that the Issuer or any Restricted Subsidiary (other than any Non-Recourse Subsidiary) incurs, assumes, guarantees, redeems, repays, retires or extinguishes any Indebtedness (other than Indebtedness incurred or repaid under any revolving credit facility unless such Indebtedness has been permanently repaid and has not been replaced) or issues or redeems Disqualified Stock or Preferred Equity subsequent to the commencement of the period for which the Fixed Charge Coverage Ratio is being calculated but prior to or simultaneously with the event for which the calculation of the Fixed Charge Coverage Ratio is made (the “Calculation Date”), then the Fixed Charge Coverage Ratio shall be calculated giving pro forma effect to such incurrence, assumption, guarantee, redemption, repayment, defeasance, discharge, retirement or extinguishment of Indebtedness, or such issuance or redemption of Disqualified Stock or Preferred Equity, as if the same had occurred at the beginning of the applicable four-quarter period.

In addition, for purposes of making the computation referred to above,

(1) Investments, acquisitions, dispositions, mergers, amalgamations, consolidations and discontinued operations (as determined in accordance with GAAP) that have been made by the Issuer or any of its Subsidiaries during the Test Period or subsequent to such Test Period and on or prior to or simultaneously with the Calculation Date shall be calculated on a pro forma basis assuming that all such Investments, acquisitions, dispositions, mergers, amalgamations, consolidations and discontinued operations (and the change in any associated fixed charge obligations and the change in Distributable Cash resulting therefrom) had occurred on the first day of the Test Period;

(2) if since the beginning of the Test Period, any Person that subsequently became a Subsidiary or was merged with or into the Issuer or any of its Subsidiaries since the beginning of such period shall have made any Investment, acquisition, disposition, merger, amalgamation, consolidation or discontinued operation that would have required adjustment pursuant to this definition, then the Fixed Charge Coverage Ratio shall be calculated giving pro forma effect thereto for such period as if such Investment, acquisition, disposition, merger, amalgamation, consolidation or discontinued operation had occurred at the beginning of the applicable Test Period;

 

17


(3) any Person that is a Restricted Subsidiary or a Subsidiary on the Calculation Date will be deemed to have been a Restricted Subsidiary or a Subsidiary, as applicable, at all times during the applicable Test Period, and any Person that is not a Restricted Subsidiary or a Subsidiary on the Calculation Date will be deemed not to have been a Restricted Subsidiary or a Subsidiary, as applicable, at any time during the Test Period;

(4) if any Indebtedness bears a floating rate of interest, the interest expense on such Indebtedness will be calculated as if the rate in effect on the Calculation Date had been the applicable rate for the entire period (taking into account any Hedging Obligation applicable to such Indebtedness);

(5) interest on a Finance Lease Obligation shall be deemed to accrue at an interest rate reasonably determined by a responsible financial or accounting officer of the Issuer to be the rate of interest implicit in such Finance Lease Obligation in accordance with GAAP; and

(6) interest on Indebtedness that may optionally be determined at an interest rate based upon a factor of a prime or similar rate, a eurocurrency interbank offered rate, or other rate, shall be deemed to have been based upon the rate actually chosen, or, if none, then based upon such optional rate chosen as the Issuer may designate.

For purposes of this definition, whenever pro forma effect is to be given to an acquisition or disposition of assets, the amount of income or earnings relating thereto and the amount of Fixed Charges associated with any Indebtedness incurred in connection therewith, the pro forma calculations shall be determined in good faith by the Issuer (and may include, for the avoidance of doubt, cost savings, operating expense reductions and synergies resulting from such Investment, acquisition, disposition, merger, amalgamation, consolidation, discontinued operation, operational change, business expansion or other transaction which is being given pro forma effect).

Fixed Charges” means, for any period, without duplication, the sum of:

(1) consolidated interest expense of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) for such period including, with respect to the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) (a) amortization of original issue discount resulting from the issuance of Indebtedness at less than par, (b) all commissions, discounts and other fees and charges owed with respect to letters of credit, bank guarantees or bankers acceptances, (c) the interest component of Finance Lease Obligations, and (d) net payments, if any made (less net payments, if any, received), pursuant to interest rate Hedging Obligations with respect to Indebtedness, but excluding (i) annual agency fees paid to the administrative agents and collateral agents under any credit facilities, (ii) costs associated with obtaining Hedging Obligations and breakage costs in respect of Hedging Obligations related to interest rates, (iii) penalties and interest relating to taxes, (iv) amortization or expensing of deferred financing fees, amendment and consent fees, debt issuance costs, commissions, fees and expenses and discounted liabilities, (v) any expensing of bridge, commitment and other financing fees and any other fees related to any acquisitions, (vi) commissions, discounts, yield and other fees and charges (including any interest expense) related to any Permitted Receivables Financing,

 

18


(vii) any accretion of accrued interest on discounted liabilities and any prepayment premium or penalty, (viii) any interest expense attributable to obligations of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) that are classified as “capital lease obligations” under GAAP due to the consolidation of variable interest entities and (ix) any “additional interest” or “liquidated damages” with respect to other securities for failure to timely comply with registration rights obligations ; plus

(2) cash dividends on any Disqualified Stock or Preferred Equity of the Issuer or any Restricted Subsidiary (other than Non-Recourse Subsidiaries), provided that any Disqualified Stock of the Issuer or any Restricted Subsidiary (other than Non-Recourse Subsidiaries) and any Preferred Equity of any Restricted Subsidiary (other than Non- Recourse Subsidiaries) is incurred in accordance with Section 4.09, plus

(3) consolidated capitalized interest of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) for such period, whether paid or accrued.

For purposes of this definition, interest on a Finance Lease Obligation shall be deemed to accrue at an interest rate reasonably determined by such Person to be the rate of interest implicit in such Finance Lease Obligation in accordance with GAAP.

GAAP” means generally accepted accounting principles in the United States of America as in effect from time to time; provided, that if any such accounting principle changes after the Issue Date, the Issuer may, at its option, elect to employ such accounting principle or (2) if elected by the Issuer by written notice to the Trustee in any accounting principles that are recognized as being generally accepted as set forth above which are in effect from time to time, in each case as in effect on the first date of the period for which the Issuer makes such an election and thereafter as in effect from time to time; provided that in each case any such election, once made, shall be irrevocable. Notwithstanding any other provision contained in this Indenture, the amount of any Indebtedness under GAAP with respect to Finance Lease Obligations shall be determined in accordance with the definition of “Finance Lease Obligations.”

Global Note Legend” means the legend set forth in Section 2.06(g)(2), which is required to be placed on all Global Notes issued under this Indenture.

Global Notes” means, individually and collectively, each of the Restricted Global Notes, the Unrestricted Global Notes and any Additional Notes issued as a Global Note, substantially in the form attached as Exhibit A-1 or Exhibit A-2, deposited with or on behalf of and registered in the name of the Depositary or its nominee, issued in accordance with Section 2.01 and Section 2.06.

Government Securities” means direct obligations of, or obligations guaranteed by, the United States of America (including any agency or instrumentality thereof) for the payment of which obligations or guarantees the full faith and credit of the United States of America is pledged and which are not callable or redeemable at the issuer’s option.

Governmental Authority” means the government of the United States or any other nation, or of any political subdivision thereof, whether state or local, and any agency, authority, instrumentality, regulatory body, court, central bank or other entity exercising executive, legislative, judicial, taxing, regulatory or administrative powers or functions of or pertaining to government.

 

19


guarantee” means a guarantee other than by endorsement of negotiable instruments for collection or deposit in the ordinary course of business, of all or any part of any Indebtedness (whether arising by agreements to keep-well, to take or pay or to maintain financial statement conditions, pledges of assets or otherwise).

Guarantee” means any guarantee of the Issuer’s obligations under this Indenture and the Notes by any Restricted Subsidiary in accordance with the provisions of this Indenture. When used as a verb, “Guarantee” shall have a corresponding meaning.

Guarantors” means, any Restricted Subsidiary that executes a Guarantee in accordance with the provisions of this Indenture, and their respective successors and assigns.

Hedging Obligations” means, with respect to any specified Person, the obligations of such Person under:

(1) currency exchange, interest rate or commodity swap agreements, currency exchange, interest rate or commodity cap agreements and currency exchange, interest rate or commodity collar agreements; and

(2) (i) agreements or arrangements designed to protect such Person against fluctuations in currency exchange, interest rates, commodity prices or commodity transportation or transmission pricing or availability; (ii) any netting arrangements, purchase and sale agreements for renewable energy credits, fuel purchase and sale agreements, swaps, options and other agreements entered into for hedging purposes, in each case, that fluctuate in value with fluctuations in energy, power or gas prices; and (iii) agreements or arrangements for commercial or trading activities with respect to the purchase, transmission, distribution, sale, lease or hedge of any energy related commodity or service.

Holdco Total Debt” means, as of any date, the sum of (1) the aggregate amount of all outstanding Indebtedness of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) on a consolidated basis consisting of Indebtedness for borrowed money, Finance Lease Obligations, purchase money obligations and debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit (but excluding any Non-Recourse Financing and Permitted Receivables Financings), plus (2) the aggregate amount of all outstanding Disqualified Stock of the Issuer and Disqualified Stock and Preferred Stock of its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) on a consolidated basis, with the amount of such Disqualified Stock or Preferred Stock, as applicable, equal to the greater of its voluntary or involuntary liquidation preference and its Maximum Fixed Repurchase Prices, determined on a consolidated basis in accordance with GAAP, as calculated with such pro forma adjustments as are appropriate and consistent with the pro forma adjustment provisions set forth in the definition of “Fixed Charge Coverage Ratio.” For purposes hereof, the “Maximum Fixed Repurchase Price” of any Disqualified Stock or Preferred Stock means the price at which such Disqualified Stock or Preferred Stock could be redeemed or repurchased by the issuer thereof in accordance with its terms or, if such Disqualified Stock or Preferred Stock cannot be so redeemed or repurchased, the fair market value of such Disqualified Stock or Preferred Stock (as determined in good faith by the Issuer), determined on any date on which Holdco Total Debt shall be required to be determined.

 

20


Holdco Debt Ratio” means, for any Test Period, the ratio of (1) Holdco Total Debt as of the end of such Test Period to (2) Distributable Cash for such Test Period, in each case with such pro forma adjustments to Holdco Total Debt and Distributable Cash as are appropriate, in each case as calculated with such pro forma adjustments as are appropriate and consistent with the pro forma adjustment provisions set forth in the definition of “Fixed Charge Coverage Ratio,” as determined in good faith by the Issuer.

Holder” means a Person in whose name a Note is registered.

IAI Global Note” means a Global Note other than a Regulation S Global Note or a Rule 144A Global Note, issued in connection with a transfer of a Note or an interest therein to an Institutional Accredited Investor in reliance on an exemption from the registration requirements of the Securities Act.

Immaterial Subsidiary” means, as of any date, any Restricted Subsidiary that does not have consolidated assets in excess of 5.0% of consolidated total assets of the Issuer and its Restricted Subsidiaries as of the last day of the applicable Test Period; provided that, the consolidated total assets (as so determined) of all Immaterial Subsidiaries shall not exceed 10.0% of consolidated total assets of the Issuer and its Restricted Subsidiaries as of the last day of the applicable Test Period; provided, further, that, any direct Wholly-Owned Subsidiary of the Issuer that owns, directly or indirectly, all or a portion of the Calcasieu Pass Project, the TransCameron pipeline, the Plaquemines Project, the Gator Express pipeline, the CP2 Project, the CP2 Express pipeline, the Delta Project and/or the Delta Express pipeline shall not, in any event, be an Immaterial Subsidiary.

Immediate Family Members” means, with respect to any individual, such individual’s child, stepchild, grandchild or more remote descendant, parent, stepparent, grandparent, spouse, former spouse, qualified domestic partner, sibling, mother-in-law, father-in-law, son-in-law and daughter-in-law (including adoptive relationships, the estate of such individual and such other individuals above) and any trust, partnership or other bona fide estate-planning vehicle the only beneficiaries of which are any of the foregoing individuals or any private foundation or fund that is controlled by any of the foregoing individuals or any donor-advised fund of which any such individual is the donor.

Indebtedness” means, with respect to any specified Person, any indebtedness of such Person (excluding accrued expenses and trade payables, except as provided in clause (5) below), whether or not contingent:

(1) in respect of borrowed money;

(2) evidenced by bonds, notes, debentures or similar instruments or letters of credit (or reimbursement agreements in respect thereof);

(3) in respect of banker’s acceptances;

 

21


(4) representing Finance Lease Obligations in respect of sale and leaseback transactions;

(5) obligations representing the balance of deferred and unpaid purchase price of any property or services with a scheduled due date more than six months after such property is acquired or such services are completed; or

(6) representing the net amount owing under any Hedging Obligations,

if and to the extent any of the preceding items (other than letters of credit and Hedging Obligations) would appear as a liability upon a balance sheet of the specified Person prepared in accordance with GAAP.

In addition, the term “Indebtedness” includes all Indebtedness of others secured by a Lien on any asset of the specified Person (whether or not such Indebtedness is assumed by the specified Person) and, to the extent not otherwise included, the guarantee by the specified Person of any Indebtedness of any other Person; provided that the amount of such Indebtedness shall be deemed not to exceed the lesser of the amount secured by such Lien and the value of the Person’s property securing such Lien.

For the avoidance of doubt and notwithstanding the foregoing, the term “Indebtedness” will not include: (i) non-interest bearing installment obligations, contingent obligations and accrued liabilities, in each case that are incurred in the ordinary course of business and are not more than 90 days past due; (ii) obligations (a) in respect of any acquisition or contribution agreement with respect to any Permitted Investment (other than obligations constituting Indebtedness pursuant to clause (5) of this definition), or (b) existing by virtue of rights of a Non- Recourse Subsidiary under a Project Obligation collaterally assigned to a creditor, which rights may be exercised pursuant to such Project Obligation against the Issuer or any Restricted Subsidiary that is party to such Project Obligation, (iii) any prepayments or deposits received from customers or obligations in respect of funds held on behalf of customers (including, without limitation, in relation to periodic purchase volume or sales incentive rebates), in each case, in the ordinary course of business, (iv) any obligations under any license, permit or approval or guarantees thereof incurred prior to the Issue Date in the ordinary course of business, (v) in connection with the purchase by the Issuer or any Restricted Subsidiary of any business or project, any post-closing payment adjustments to which the seller may become entitled to the extent such payment is determined by a final closing balance sheet or such payment depends on the performance of such business after the closing (other than obligations constituting Indebtedness pursuant to clause (5) of this definition); provided, however, that, at the time of closing, the amount of any such payment is not determinable and, to the extent such payment thereafter becomes fixed and determined, the amount is paid in a timely manner; and (vi) any Capital Stock.

Indenture” means this indenture, as amended, supplemented or otherwise modified from time to time.

Indirect Participant” means a Person who holds a beneficial interest in a Global Note through a Participant.

 

22


Initial Additional 2028 Notes” has the meaning assigned to it in the recitals to this Indenture.

Initial Additional 2031 Notes” has the meaning assigned to it in the recitals to this Indenture.

Initial Notes” means the Initial 2028 Notes and the Initial 2031 Notes.

Initial 2028 Notes” has the meaning assigned to it in the recitals to this Indenture. “Initial 2031 Notes” has the meaning assigned to it in the recitals to this Indenture. “Initial Purchasers” means J.P. Morgan Securities LLC, BofA Securities, Inc., Goldman Sachs & Co. LLC, Scotia Capital (USA) Inc., BBVA Securities Inc., Deutsche Bank Securities Inc., ICBC Standard Bank Plc, ING Financial Markets LLC, Mizuho Securities USA LLC, MUFG Securities Americas Inc., Natixis Securities Americas LLC, RBC Capital Markets, LLC, Santander US Capital Markets LLC, SMBC Nikko Securities America, Inc., Wells Fargo Securities, LLC, DZ Financial Markets LLC, Loop Capital Markets LLC, National Bank of Canada Financial Inc., Regions Securities LLC and R. Seelaus & Co., LLC.

Institutional Accredited Investor” means an institution that is an “accredited investor” as defined in Rule 501(a)(1), (2), (3) or (7) under the Securities Act, who are not also QIBs.

Interest Payment Date” means June 1 and December 1 of each year, beginning on December 1, 2023.

Investment” means, with respect to any Person, all direct or indirect investments by such Person in other Persons in the forms of loans (including guarantees or other obligations), advances or capital contributions, purchases or other acquisitions for consideration of Indebtedness, Equity Interests or other securities.

For purposes of Section 4.07, “Investment” will include the portion (proportionate to the Issuer’s equity interest in a Restricted Subsidiary to be designated as an Unrestricted Subsidiary) of the Fair Market Value of the net assets of such Restricted Subsidiary of the Issuer at the time that such Restricted Subsidiary is designated an Unrestricted Subsidiary; provided, however, that upon a redesignation of such Subsidiary as a Restricted Subsidiary, the Issuer will be deemed to continue to have a permanent “Investment” in an Unrestricted Subsidiary in an amount (if positive) equal to (a) the Issuer’s “Investment” in such Subsidiary at the time of such redesignation less (b) the portion (proportionate to the Issuer’s equity interest in such Subsidiary) of the Fair Market Value of the net assets of such Subsidiary at the time that such Subsidiary is so re-designated a Restricted Subsidiary.

Investment Grade Rating” means: (a) with respect to S&P, any of the categories from and including AAA to and including BBB- (or equivalent successor categories); (b) with respect to Moody’s, any of the categories from and including Aaa to and including Baa3 (or equivalent successor categories); and (c) with respect to Fitch, any of the categories from and including AAA to and including BBB- (or equivalent successor categories).

 

23


Investors” means (a) the VGP Investor and (b) the Management Investors and (c) other holders of Equity Interests in the Issuer on the Issue Date.

Issue Date” means May 26, 2023.

Issuer” means Venture Global LNG, Inc., and any and all successors thereto.

IPO” means (a) the issuance by the Issuer or any Parent Entity of common Equity Interests in an underwritten public offering (other than a public offering pursuant to a registration statement on Form S-8 or comparable filing in any other applicable jurisdiction) pursuant to an effective registration statement filed with the Commission or any other comparable Governmental Authority in any other applicable jurisdiction or pursuant to Rule 144A (whether as a primary offering, a secondary public offering or a combination thereof) and (b) any other transaction or series of related transactions (including any acquisition by, or combination or other similar transaction with, a special purpose acquisition company that (i) is an entity organized or existing under the laws of the U.S., any state thereof or the District of Columbia, (ii) prior to the IPO engaged in no material business or activity other than those related to becoming and acting as a special purpose acquisition company and consummating the IPO and (iii) immediately prior to the IPO had no material assets other than cash and Cash Equivalents) that results in any of the common Equity Interests of the Issuer or any Parent Entity being publicly traded on any U.S. national securities exchange or over- the-counter market or any analogous exchange or market.

IPO Reorganization Transactions” means, collectively, the transactions effected in connection with and reasonably related to consummating an IPO.

Joint Venture” means any Person that is not a direct or indirect Subsidiary of the Issuer in which the Issuer or any of its Restricted Subsidiaries makes any Investment.

Junior Lien Obligations” means the obligations with respect to Indebtedness permitted to be incurred under this Indenture, which is by its terms intended to be secured by a Lien on the Collateral that is junior to the Lien on the Collateral that secures the Notes and the Guarantees; provided such Lien is not prohibited by the terms of this Indenture; provided, further, that (i) the holders of such Indebtedness, or the representative of such holders, shall become party to an Applicable Intercreditor Agreement and any other applicable intercreditor agreements, in each case, agreeing to be bound thereby and (ii) the Issuer has designated such Indebtedness as “Junior Lien Obligations” under such Applicable Intercreditor Agreement.

Junior Lien Representative” means in the case of any Junior Lien Obligations incurred after the Issue Date, the trustee, administrative agent, collateral agent, security agent or similar agent under the credit agreement, indenture or other operative documents governing such Junior Lien Obligations that is named as the representative in respect of such Junior Lien Obligations in the Junior Lien Intercreditor Agreement or joinder thereto.

Junior Lien Secured Parties” means with respect to any Junior Lien Obligation, all lenders, holders, trustees or agents to which such Junior Lien Obligations are owing.

Lien” means, with respect to any asset:

 

24


(1) any mortgage, deed of trust, deed to secure debt, lien (statutory or otherwise), pledge, hypothecation, encumbrance, restriction, collateral assignment, charge or security interest in, on or of such asset;

(2) the interest of a vendor or a lessor under any conditional sale agreement, capital lease or title retention agreement (or any financing lease having substantially the same economic effect as any of the foregoing) relating to such asset; and

(3) in the case of Equity Interests or debt securities, any purchase option, call or similar right of a third party with respect to such Equity Interests or debt securities.

“Limited Condition Transaction” means (a) the entering into or consummation of any transaction (including any Restricted Payment, Change of Control, acquisition (whether by merger, consolidation or other business combination or the acquisition of capital stock, Indebtedness or otherwise) or other Investment by the Issuer or one or more of its Restricted Subsidiaries).

Long Derivative Instruments” means, as to any person, a Derivative Instrument (i) the value of which to such person generally increases, and/or the payment or delivery obligations of such person under which generally decrease, with positive changes in the financial performance and/or position of the Issuer and/or (ii) the value of which to such person generally decreases, and/or the payment or delivery obligations of such person under which generally increase, with negative changes in the financial performance and/or position of the Issuer.

Management Advances” means loans or advances made to, or guarantees with respect to loans or advances made to, directors, officers, employees or consultants (or their respective Controlled Investment Affiliates or Immediate Family Members) of any Parent Entity, the Issuer or any Restricted Subsidiary:

(1) (a) in respect of travel, entertainment, relocation or moving related expenses, payroll advances, deferred compensation and other analogous or similar expenses or payroll expenses, in each case incurred in the ordinary course of business or consistent with past practice or industry norms, or in connection with any Investment or acquisition (by meter, consolidation, amalgamation or otherwise) that is not prohibited by this Indenture, or (b) for purposes of funding any such Person’s purchase or redemption of Capital Stock (or similar obligations) of the Issuer, its Subsidiaries or any Parent Entity that is not prohibited by Section 4.07;

(2) in respect of relocation or moving related expenses, payroll advances and other analogous or similar expenses or payroll expenses, in each case incurred in connection with any closing or consolidation of any facility or office; or

(3) not exceeding $10 million in the aggregate outstanding at the time of incurrence.

Management Investors” means any individual who is a future, current or former officer, director, manager, member, member of management, employee, consultant or independent contractor of the Issuer, any Subsidiary or any Parent Entity who are (directly or indirectly through one or more investment vehicles) holders of Equity Interests in the Issuer and/or any Parent Entity and their Permitted Transferees.

 

25


Market Capitalization” means an amount equal to (i) the total number of issued and outstanding shares of common Capital Stock of the Issuer or any Parent Entity on the date of the declaration of a Restricted Payment permitted pursuant to clause (20) of Section 4.07(b) multiplied by (ii) the arithmetic mean of the closing prices per share of such common Capital Stock on the principal securities exchange on which such common Capital Stock is traded for the 30 consecutive trading days immediately preceding the date of declaration of such Restricted Payment.

Market Intercreditor Agreement” means an intercreditor or subordination agreement or arrangement (which may take the form of a “waterfall” or similar provision) the terms of which are (a) consistent with market terms governing intercreditor arrangements for the sharing or subordination of Liens or arrangements relating to the distribution of payments in respect of Collateral, as applicable, at the time the applicable agreement or arrangement is proposed to be established in light of the type of Indebtedness subject thereto or (b) in the event an Intercreditor Agreement has been entered into after the Issue Date, the terms of which are, taken as a whole, not materially less favorable to the holders of the Notes than the terms of such Intercreditor Agreement to the extent such agreement governs similar priorities, in each case of clauses (a) and (b) as determined by the Issuer in good faith.

Net Proceeds” means the aggregate cash proceeds received by the Issuer or any of its Restricted Subsidiaries in respect of any Asset Sale (including, without limitation, any cash received upon the sale or other disposition of any non-cash consideration or Cash Equivalents substantially concurrently received in any Asset Sale), net of (i) the direct costs relating to such Asset Sale, including, without limitation, legal, accounting and investment banking fees, and sales commissions, and any relocation expenses incurred as a result of the Asset Sale, (ii) all Taxes paid or reasonably estimated to be payable as a result of the Asset Sale, (iii) all distributions and other payments required to be made to minority interest holders (other than the Issuer or any Subsidiary) in Subsidiaries or Joint Ventures as a result of such Asset Sale, (iv) all payments made on any Indebtedness which is secured by any assets subject to such Asset Sale, in accordance with the terms of any Lien upon such assets, provided that if such Indebtedness is revolving Indebtedness the related commitments are terminated, or which by applicable law are required to be repaid out of the proceeds from such Asset Sale, (v) any funded escrow established pursuant to the documents evidencing such sale or disposition to secure and indemnification obligation on adjustments to the purchase price associated with any such Asset Sale, and (vi) any reserve against liabilities associated with such Asset Sale, including pension and other post-employment benefit liabilities, liabilities related to environmental matters and indemnification obligations associated with such Asset Sale, with any subsequent reduction of the reserve other than by payments made and charged against the reserved amount to be deemed a receipt of cash.

Net Short” means, with respect to a holder or beneficial owner, as of a date of determination, either (i) the value of its Short Derivative Instruments exceeds the sum of (x) the value of its Notes plus (y) the value of its Long Derivative Instruments as of such date of determination or (ii) it is reasonably expected that such would have been the case were a Failure to Pay or Bankruptcy Credit Event (each as defined in the 2014 ISDA Credit Derivatives Definitions) to have occurred with respect to the Issuer immediately prior to such date of determination.

 

26


Non-Recourse Financing” means any Indebtedness (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness):

(1) as to which no Recourse Person provides any guarantee or other credit support (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness) or is directly or indirectly liable (as a guaranteeing person or otherwise) or has granted a Lien on any of its assets as security (or has any obligation, contingent or otherwise, to do so), other than, in each case, (i) customary carve-out matters for which a Recourse Person acts as a guarantor in connection with such Indebtedness, such as, without limitation, fraud, misappropriation, breach of representation and warranty and misapplication, (ii) any guarantees or other credit support of such Indebtedness by a Recourse Person made pursuant to Section 4.09(a) or that would otherwise constitute Permitted Debt, in each case, so long as such Recourse Person becomes a Guarantor to the extent required under Section 4.16, (iii) any Permitted Project Undertakings, (iv) any guarantees or other credit support in connection with any ECR Transaction, (v) any Standard Securitization Undertakings, and (vi) any Permitted Intercompany Activities; and

(2) which is incurred by one or more Non-Recourse Subsidiaries (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness) for the purpose of, or in connection with, any financing (or refinancing) of all or any portion of any Project to which such Non-Recourse Subsidiaries relate, all or any portion of any Project Costs relating to any such Project, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith; provided that, to the extent such Non-Recourse Financing is incurred by a Non-Recourse Subsidiary that is an obligor under any Non-Recourse Financing relating to the applicable Project that is not structurally or otherwise subordinated or junior to any other Non-Recourse Financing for such Project, the proceeds of such Non-Recourse Financing being incurred may be used for the purpose of, or in connection with, any financing (or refinancing) of all or any portion of any one or more other Projects, all or any portion of any Project Costs relating to any such one or more other Projects, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith, so long as such use of proceeds is permitted under the terms of each Non-Recourse Financing that is then outstanding in respect of the Project to which such Non-Recourse Subsidiary is a party (and not pursuant to an amendment or waiver of any such Non-Recourse Financing in contemplation thereof).

Non-Recourse Subsidiary” means each of the following, as determined at any time and from time to time by the Issuer in good faith:

(1) any Restricted Subsidiary of the Issuer that (i) is a Project Company, (ii) has no Subsidiaries and owns no material businesses or assets other than those Subsidiaries, businesses and assets reasonably necessary, appropriate or desirable for, or reasonably

 

27


related or ancillary to, no more than one individual Project or other activities reasonably related or ancillary thereto, or necessary, appropriate or desirable in connection therewith, and (iii) has no Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit then outstanding other than any Non-Recourse Financing, Indebtedness arising from Permitted Intercompany Activities or otherwise between or among the Issuer and any Restricted Subsidiaries not prohibited by this Indenture, and guarantees of Indebtedness of any other Person (other than the Issuer or any Restricted Subsidiary) that are otherwise not prohibited by this Indenture; and

(2) any Restricted Subsidiary of the Issuer that (i) is the direct or indirect owner of all or a majority (including together with one or more other Non-Recourse Subsidiaries) of the Equity Interests in one or more Persons, each of which meets the qualifications set forth in clause (1) of this definition, (ii) has no Subsidiaries other than Subsidiaries each of which meets the conditions set forth in clause (1) or clause (2)(i) of this definition, (iii) owns no material businesses or assets other than those businesses and assets reasonably necessary, appropriate or desirable for, or reasonably related or ancillary to, no more than one individual Project or other activities reasonably related or ancillary thereto, or necessary, appropriate or desirable in connection therewith, and (iv) has no Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit then outstanding other than any Non-Recourse Financing, Indebtedness arising from Permitted Intercompany Activities or otherwise between or among the Issuer and any Restricted Subsidiaries not prohibited by this Indenture, and guarantees of Indebtedness of any other Person (other than the Issuer or any Restricted Subsidiary) that are otherwise not prohibited by this Indenture.

As of the Issue Date, each of Venture Global Calcasieu Pass Holding, LLC, Calcasieu Pass Funding, LLC, Calcasieu Pass Holdings, LLC, Calcasieu Pass Pledgor, LLC, Venture Global Calcasieu Pass, LLC, TransCameron Pipeline, LLC, Calcasieu Tug Services, LLC, Calcasieu Pass Operations, LLC, TransCameron Operations, LLC, Venture Global CCS Cameron, LLC, Venture Global Plaquemines LNG Holding II, LLC, Venture Global Plaquemines LNG Holding, LLC, Plaquemines LNG Funding, LLC, Plaquemines LNG Holdings Pledgor, LLC, Plaquemines LNG Holdings, LLC, Plaquemines LNG Pledgor, LLC, Venture Global Plaquemines LNG, LLC, Venture Global Gator Express, LLC, Plaquemines Tug Services, LLC, Plaquemines LNG Operations, LLC, Venture Global CCS Plaquemines, LLC, Gator Express Operations, LLC, Venture Global CP2 LNG Holding, LLC, Venture Global CP2 LNG, LLC, Venture Global CP Express, LLC, Venture Global Delta LNG, LLC, Venture Global Delta Express, LLC, Venture Global Midstream Holdings, LLC, and VG LNG Shipping, LLC shall constitute Non-Recourse Subsidiaries.

“Non-U.S. Person” means a Person who is not a U.S. Person.

Note Documents” means this Indenture (including any Guarantee), the Notes and the Security Documents.

 

28


Note Obligations” means all obligations of the Issuer and the Guarantors under the Note Documents.

Notes” means the Initial Notes and any Additional Notes. Unless the context requires otherwise, all references to “Notes” for all purposes of this Indenture shall include any Additional Notes that are actually issued and authenticated. The Initial Notes of any series and all Additional Notes of such series shall be treated as a single class for all purposes under this Indenture, and unless the context otherwise requires, all references to the Notes of any series shall include the Initial Notes and any Additional Notes of such series.

Notes Parties” means, collectively, the Trustee, the Agents, each other agent, and the Holders, in each case, under this Indenture and the Collateral Agent under the Collateral Agency Agreement.

Offering Memorandum” means, collectively, the Issuer’s final offering memorandum dated May 19, 2023 relating to the sale of the Initial Notes, and the Issuer’s final offering memorandum dated May 24, 2023 relating to the sale of the Initial Additional 2028 Notes and the Initial Additional 2031 Notes.

Officer” means, with respect to any Person, the Chairman of the Board of Directors, the Chief Executive Officer, the President, the Chief Operating Officer, the Chief Financial Officer, the Treasurer, any Assistant Treasurer, the Controller, the Secretary or any Vice-President of such Person.

Officer’s Certificate” means a certificate which meets the requirements set forth in Section 13.02 and Section 13.03, and which is signed by an Officer of the Issuer, a Guarantor or any successor Person to the Issuer or any Guarantor, as the case may be, and delivered to the Trustee.

Opinion of Counsel” means an opinion or opinions from legal counsel which opinion is reasonably acceptable to the Trustee and meets the requirements of Section 13.02 and Section Section 13.03. The counsel may be an employee of, or counsel to, the Issuer, any Subsidiary of the Issuer or the Trustee.

Parent Entity” means the Issuer and any Person that is the direct or indirect parent of the Issuer and of which the Issuer is a direct or indirect Subsidiary.

Participant” means, with respect to the Depositary, Euroclear or Clearstream, a Person who has an account with the Depositary, Euroclear or Clearstream, respectively (and, with respect to DTC, shall include Euroclear and Clearstream).

Permitted Business” means (a)(i) any businesses, services or activities engaged in by the Issuer or any of its Subsidiaries on the Issue Date, (ii) any Project, and any businesses, services or activities engaged in by the Issuer or any of its Subsidiaries in connection with any Project, including in connection with preparing for, and implementing any Project, and (iii) any businesses, services and activities engaged in by the Issuer or any of its Subsidiaries that are reasonably related, complementary, incidental, synergistic, ancillary or similar to any of the foregoing or are, in whole or in part, extensions, expansions or developments of any thereof, and (b) where the context requires, any Person engaged primarily in the businesses, services or activities described in clause (a) of this definition, in each case, as determined by the Issuer in good faith.

 

29


Permitted Business Investments” means Investments by the Issuer or any of its Restricted Subsidiaries in any Person (including any Joint Venture or Unrestricted Subsidiary); provided that:

(1) such Person is engaged in a Permitted Business;

(2) except in the case of any such Investment by a Non-Recourse Subsidiary, at the time of such Investment and immediately thereafter, the Issuer could incur $1.00 of additional Indebtedness under the Holdco Debt Ratio test set forth in Section 4.09(a); and

(3) if, upon consummation of such Investment, such Person will be a Restricted Subsidiary, then if either such Restricted Subsidiary will be a Recourse Person and has outstanding any Indebtedness, or such Person will be a Non-Recourse Subsidiary and has outstanding Indebtedness at the time of such Investment that is recourse to any Recourse Person, then in each case such Person could, at the time such Investment is made, incur such Indebtedness at such time pursuant to Section 4.09.

Permitted Holder” means (a) the Investors and (b) any Person with which one or more Investors form a “group” (within the meaning of Section 14(d) of the Exchange Act as in effect on the date of this Indenture) so long as, in the case of this clause (b), such one or more Investors directly or indirectly collectively Beneficially Own more than 50% of the aggregate voting Equity Interests that are Beneficially Owned by the group.

Permitted Intercompany Activities” means any transactions between or among the Issuer and its Restricted Subsidiaries that are entered into in the ordinary course of business, consistent with past practice or industry norms, or that are reasonably necessary, appropriate or advisable in connection with the ownership or operation of the business of the Issuer and its Restricted Subsidiaries, including, but not limited to, (i) payroll, cash management, netting, overdraft protection, purchasing, insurance and hedging arrangements; (ii) management, technology and licensing arrangements; and (iii) marketing and other professional services and shipping and maintenance arrangements.

Permitted Investment” means:

(1) any Investment in the Issuer or any Restricted Subsidiary;

(2) any Investment in a Person, if as a result of such Investment:

(i) such Person becomes a Restricted Subsidiary; or

(ii) such Person is merged, consolidated or amalgamated with or into, or transfers all or substantially all of its assets to, or is liquidated into, the Issuer or a Restricted Subsidiary;

(3) any Investment in cash or Cash Equivalents;

 

30


(4) any Investment made as a result of the receipt of non-cash consideration from an Asset Sale that was made pursuant to and in compliance with Section 4.10 or any other disposition of assets not constituting an Asset Sale;

(5) any Investment existing on the Issue Date and any extension, modification or renewal of any such Investments (but not any such extension, modification or renewal to the extent it involves additional advances, contributions or other investments of cash or property, except as otherwise permitted under this Indenture);

(6) (a) any acquisition of assets solely in exchange for the issuance of Equity Interests (other than Disqualified Stock) of the Issuer and (b) advances and prepayments for asset purchases (i) in the ordinary course of business or (ii) if such asset purchases would otherwise constitute a Permitted Investment;

(7) (i) extensions of trade credit (or notes receivable arising from such grant) and deposits, prepayments and other credits to suppliers made in the ordinary course of business, and Investments received in compromise or resolution thereof from financially troubled account debtors or in connection with the bankruptcy or reorganization of suppliers or customers or in settlement of delinquent obligations of, or other disputes with, suppliers and customers, and other credits to suppliers in the ordinary course of business, or (ii) any Investments received in compromise or resolution of litigation, arbitration or other disputes;

(8) Hedging Obligations permitted under clause (13) of Section 4.09(b);

(9) Investments in the Notes, including repurchases of the Notes;

(10) any Investment in prepaid expenses, negotiable instruments held for collection and lease, utility, workers’ compensation and performance and other similar deposits;

(11) Management Advances;

(12) Permitted Business Investments; provided, however, that if any Investment pursuant to this clause (12) is made in any Person that is not a Restricted Subsidiary of the Issuer at the date of the making of such Investment and such Person becomes a Restricted Subsidiary after such date, such Investment shall thereafter be deemed to have been made pursuant to clause (1) above and shall cease to have been made pursuant to this clause (12);

(13) (i) any guarantee of Indebtedness permitted to be incurred pursuant to Section 4.09, (ii) any guarantee of performance obligations in the ordinary course of business, and (iii) the creation of Liens on the assets of the Issuer or any Restricted Subsidiary in compliance with Section 4.12;

(14) Investments consisting of the licensing or contribution of intellectual property pursuant to joint marketing arrangements with other Persons;

 

31


(15) extensions of credit to (and guarantees to the benefit of) customers, suppliers, vendors, contractors and service providers in the ordinary course of business including, advances to customers and suppliers that are recorded as accounts receivable, prepaid expenses or deposits on the balance sheet of the Issuer and its Restricted Subsidiaries in the ordinary course of business;

(16) other Investments made since the Issue Date in any Person having an aggregate Fair Market Value that are at that time outstanding (measured, with respect to each Investment, on the date such Investment was made and without giving effect to subsequent changes in value) not to exceed the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period; provided that if any Investment pursuant to this clause (16) is made in any Person that is not a Restricted Subsidiary of the Issuer at the date of the making of such Investment and such Person becomes a Restricted Subsidiary of the Issuer after such date, such Investment shall thereafter be deemed to have been made pursuant to clause (1) above and not this clause (16);

(17) acquisitions or other Investments consisting of assets, equipment, inventory, supplies, materials and property intended for use in any Project;

(18) payroll, travel and similar advances to cover matters that are expected at the time of such advances ultimately to be treated as expenses for accounting purposes and that are made in the ordinary course of business;

(19) trade receivables and prepaid expenses, in each case arising in the ordinary course of business; provided that such receivables and prepaid expenses would be recorded as assets in accordance with GAAP;

(20) earnest money deposits may be made to the extent required in connection with acquisitions permitted under this Indenture or the acquisition or real property and related assets;

(21) Investments by the Issuer or any Restricted Subsidiary consisting of deposits, prepayment and other credits to suppliers or landlords made in the ordinary course of business;

(22) Investments in certificates of deposit, banker’s acceptances and time deposits maturing within one year from the date of acquisition thereof issued or guaranteed by or placed with, and money market deposit accounts issued or offered by, any domestic office of any commercial bank that has a combined capital and surplus and undivided profits of not less than $500.0 million;

(23) Investments pursuant to any Project Obligations, any Permitted Project Undertaking or any Permitted Transaction;

(24) [reserved];

 

32


(25) Investments the payment for which consists of Equity Interests (other than Disqualified Stock, except to the extent issued by the Issuer to one of its Restricted Subsidiaries) of the Issuer, or redemptions in whole or in part of any of the Equity Interests of the Issuer (other than Disqualified Stock, except to the extent issued by the Issuer to one of its Restricted Subsidiaries) or with the proceeds from substantially concurrent equity contributions or new Equity Interests (and in no event shall such contribution or issuance so utilized increase the amount available as Incremental Funds for Restricted Payments pursuant to Section 4.07(a) or be duplicative of any payments pursuant to Section 4.07(b)) (other than Disqualified Stock, except to the extent issued by the Issuer to one of its Restricted Subsidiaries);

(26) any transaction to the extent it constitutes an Investment that is permitted by and made in accordance with Section 4.11(b) (except transactions described in clauses (2), (7), (11) and (14) of Section 4.11(b);

(27) any Investment by any Captive Insurance Subsidiary in connection with the provision of insurance to the Issuer or any of its Subsidiaries, which Investment is made in the ordinary course of business or consistent with past practice or industry norms of such Captive Insurance Subsidiary, or by reason of applicable law, rule, regulation or order, or that is required or approved by any regulatory authority having jurisdiction over such Captive Insurance Subsidiary or its business, as applicable;

(28) Investments in connection with any Permitted Intercompany Activities and, to the extent deemed reasonably necessary by the Issuer in good faith for the consummation of, any IPO Reorganization Transaction or any Tax Restructuring;

(29) guarantees of leases or other obligations that do not constitute Indebtedness, in each case, entered into in the ordinary course of business or consistent with past practice or industry norms;

(30) Investments in or relating to a Receivables Subsidiary that, in the good faith determination of Issuer are necessary or advisable to effect any Permitted Receivables Financing (including any contribution of replacement or substitute assets to such subsidiary) or any repurchase obligation in connection therewith;

(31) Investments in connection with any Permitted Receivables Financing permitted under this Indenture, the contribution, sale or other transfer of Permitted Receivables Financing Assets, cash or Cash Equivalents made in connection with a Permitted Receivables Financing permitted under this Indenture or repurchases in connection with the foregoing (including the contribution or lending of cash and Cash Equivalents to Subsidiaries to finance the purchase of receivables or related assets from the Issuer or any Restricted Subsidiary or to otherwise fund required reserves, the contribution of replacement or substitute assets to a Receivables Subsidiary and Investments of funds held in accounts permitted or required by the arrangements governing such Permitted Receivables Financing or any related Indebtedness); and

(32) Investments in Joint Ventures having an aggregate fair market value taken together with all other Investments made pursuant to this clause (32) that are at that time outstanding not to exceed the greater of (A) $500 million and (B) 15.0% of Distributable

 

33


Cash for the applicable Test Period (in each case, determined on the date such Investment is made, with the fair market value of each Investment being measured at the time made and without giving effect to subsequent changes in value), plus the amount of any returns (including dividends, payments, interest, distributions, returns of principal, profits on sale, repayments, income and similar amounts) in respect of such investments; provided, however, that if any Investment pursuant to this clause (32) is made in any Person that is not a Restricted Subsidiary of the Issuer at the date of the making of such Investment and such Person becomes a Restricted Subsidiary after such date, such Investment shall thereafter be deemed to have been made pursuant to clause (1) above and shall cease to have been made pursuant to this clause (32).

For purposes of determining compliance with this definition, in the event that a proposed Investment (or a portion thereof) meets the criteria of clauses (1) through (32) above, the Issuer will be entitled to divide or classify or later divide or reclassify (based on circumstances existing on the date of such reclassification) such Investment (or a portion thereof) between such clauses (1) through (32) in any manner that otherwise complies with this definition.

Permitted Liens” means:

(1) Liens securing Indebtedness (i) under Credit Facilities incurred pursuant to clause (1) of Section 4.09(b) or (ii) incurred pursuant to the Holdco Debt Ratio test set forth Section 4.09(a); provided, however, that no such Liens may be created upon any asset or property that is not Collateral unless the Notes (or a Guarantee, in the case of a Lien on assets or property of a Guarantor) are equally and ratably secured with, or prior to, such Indebtedness so long as such Indebtedness is so secured (except that Liens securing subordinated Indebtedness shall be expressly subordinate to any Lien securing the Notes to at least the same extent such subordinated Indebtedness is subordinate to the Notes or such Guarantee, as the case may be);

(2) Liens on property (including Capital Stock) of a Person existing at the time such Person becomes a Restricted Subsidiary or is merged with or into or consolidated with the Issuer or any of its Restricted Subsidiaries; provided that such Liens were in existence prior to the contemplation of such Person becoming a Restricted Subsidiary or such merger or consolidation, were not incurred in contemplation thereof and do not extend to any assets other than those of the Person that becomes a Restricted Subsidiary or is merged with or into or consolidated with the Issuer or any Restricted Subsidiary;

(3) Liens on property existing at the time the Issuer or any of its Restricted Subsidiaries acquires such property; provided that such Liens were in existence prior to the contemplation of such acquisition, were not incurred in contemplation thereof and do not extend to any other assets of the Issuer or any of its Restricted Subsidiary;

(4) Liens securing Indebtedness under Bank Product Obligations, cash pooling arrangements and Hedging Obligations, which obligations are permitted by clause (13) of Section 4.09(b) and Liens securing or arising by reason of any netting or set-off arrangement entered into in the ordinary course of banking or other trading activities;

 

34


(5) Liens existing on the Issue Date;

(6) Liens in favor of the Issuer or any of its Restricted Subsidiaries;

(7) Liens for Taxes, statutory Liens of landlords, banks (and rights of set-off), of carriers, warehousemen, mechanics, repairmen, workmen and materialmen, and other Liens imposed by law;

(8) Liens incurred in the ordinary course of business in connection with workers’ compensation, unemployment insurance and other types of social security, or pledges or deposits to secure the performance of tenders, statutory obligations, surety and appeal bonds, bids, leases, concessions, government contracts, trade contracts, performance and return-of-money bonds and other similar or related obligations (exclusive of obligations for the payment of borrowed money or other Indebtedness);

(9) Liens relating to current or future escrow arrangements securing Indebtedness of the Issuer or any Guarantor (including, without limitation, arrangements for the escrow of the proceeds of Indebtedness pending consummation of an acquisition);

(10) Liens on the Capital Stock or any assets or properties of, or advances or loans to, Non-Recourse Subsidiaries (i) either securing any Non-Recourse Financing or any Project Obligations of one or more Non-Recourse Subsidiaries or (ii) or permitted pursuant to the terms thereof or by a waiver of such terms;

(11) any other Liens securing Indebtedness permitted under clauses (4), (7), (17), (18), (22), (23) or (24) of Section 4.09(b); provided that (i) Liens securing obligations relating to any Indebtedness, Disqualified Stock or Preferred Stock to be incurred pursuant to clause (4) of Section 4.09(b) extend only to the assets so purchased, leased, developed, expanded, constructed, installed, replaced, repaired, refurbished, repositioned or improved or subject to such Sale and Leaseback (plus improvements, accessions, proceeds or dividends or distributions in respect thereof, or replacements of any thereof); provided, further, that individual financings of assets provided by one lender or group of lenders may be cross-collateralized to other financings of assets by such lender or group of lenders; (ii) Liens securing obligations relating to any Indebtedness permitted to be incurred pursuant to clause (24) of Section 4.09(b) relate only to obligations relating to Refinancing Indebtedness that is secured by Liens on all or a portion of the same assets or the same categories or types of assets as the assets (plus improvements, accessions, proceeds or dividends or distributions in respect thereof, or replacements of any thereof) that secured (or, under the written arrangements under which the original Lien arose, could secure) the Indebtedness being refinanced; and (iii) Liens securing Indebtedness permitted to be incurred pursuant to clause (7)(y) of Section 4.09(b) shall only be permitted if such Liens are limited to all or a part of the same property or assets, including Capital Stock, acquired (plus improvements, accessions, proceeds or dividends or distributions in respect thereof, or replacements or any thereof), or of a Person acquired or merged, amalgamated or consolidated with or into the Issuer or any Restricted Subsidiary, in any transaction to which such Indebtedness relates and such Indebtedness was not incurred in contemplation of such transaction;

 

35


(12) Liens granted in favor of a Governmental Authority, including any decommissioning obligations, by a Non-Recourse Subsidiary when required by such Governmental Authority in connection with the operations of such Non-Recourse Subsidiary in the ordinary course of its business;

(13) Liens on any property or assets of any Non-Recourse Subsidiary arising out of conditional sale, title retention, hire purchase, consignment or similar arrangements for the sale or purchase of goods entered into in the ordinary course of business or consistent with past practice or industry norms;

(14) any interest or title of a lessor or sublessor under any lease or sublease of real estate permitted hereunder (or with respect to any deposits or reserves posted thereunder);

(15) Liens solely on any cash earnest money deposits made by the Issuer or any of its Restricted Subsidiaries in connection with any letter of intent or purchase agreement permitted hereunder;

(16) purported Liens evidenced by the filing of precautionary UCC financing statements relating solely to (i) operating leases of personal property entered into in the ordinary course of business, (ii) the sale of accounts receivable and/or (iii) the sale of Permitted Receivables Financing Assets and related assets in connection with any Permitted Receivables Financing;

(17) Liens in favor of customs and revenue authorities arising as a matter of law to secure payment of customs duties in connection with the importation of goods;

(18) any zoning or similar law or right reserved to or vested in any governmental office or agency to control or regulate the use of any real property;

(19) non-exclusive outbound licenses of patents, copyrights, trademarks and other intellectual property rights granted by the Issuer or any of its Restricted Subsidiaries in the ordinary course of business and not interfering in any respect with the ordinary conduct of or materially detracting from the value of the business of the Issuer or such Restricted Subsidiary;

(20) Liens given to a public authority or other service provider or any other Governmental Authority when required by such public authority or other service provider or other Governmental Authority in connection with the operations of such person in the ordinary course of business;

(21) any agreement (or provisions therein) to lease, option to lease, license, sub- lease or other right to occupancy assumed or entered by or on behalf of the Issuer or any Restricted Subsidiary in the ordinary course of its business;

(22) reservations, limitations, provisos and conditions, if any, expressed in any grants, permits, licenses or approvals from any Governmental Authority or any similar authority;

 

36


(23) Liens in the nature of restrictions on changes in the direct or indirect ownership or control of any Non-Recourse Subsidiary;

(24) Liens in the nature of rights of first refusal, rights of first offer, purchase options and similar rights in respect of the Equity Interests or assets of Non-Recourse Subsidiaries included in documentation evidencing contemplated purchase and sale transactions permitted under this Indenture, any Non-Recourse Financing or any Project Obligations;

(25) Liens securing insurance premium financing arrangements;

(26) Liens in favor of credit card companies pursuant to agreements therewith;

(27) Liens on real estate in connection with the financing of the acquisition or development thereof; provided that facilities are or will be located on such property or assets primarily for the use of the Issuer or any of its Subsidiaries;

(28) [reserved];

(29) Liens on assets pursuant to merger agreements, stock or asset purchase agreements and similar agreements in respect of the disposition of such assets;

(30) minor survey exceptions, minor encumbrances, minor defects or irregularities in title, easements or reservations of, or rights of others for, licenses, rights of way, servitudes, access rights, sewers, electric lines, open space and conservation easements, railways, water, drainage, gas and oil pipelines, light, power, internet or cable television services, telegraph and telephone lines, other utilities and other similar purposes, or zoning or other restrictions as to the use of real property, not interfering in any material respect with the conduct of the business of the Issuer and its Restricted Subsidiaries;

(31) Liens deemed to exist in connection with repurchase agreements and other similar Investments to the extent such Investments are permitted under this Indenture;

(32) Liens on the Capital Stock of any Unrestricted Subsidiary or Joint Venture to secure Indebtedness of such Unrestricted Subsidiary or Joint Venture;

(33) Liens securing Indebtedness in an aggregate principal amount not to exceed, as of the date of incurrence of such Lien or Indebtedness secured thereby, the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

(34) Liens created by or resulting from any litigation or other proceedings or resulting from operation of law with respect to any attachment, judgments, writs, awards, warrants, orders or similar Liens to the extent that such litigation, other proceedings, attachments, judgments, writs, awards, warrants or orders do not cause or constitute an Event of Default;

(35) Liens securing any security given to a public authority or other service provider or any other Governmental Authority when required by such utility or other Governmental Authority in connection with the operations of such person in the ordinary course of its business;

 

37


(36) Liens securing the Notes issued on the Issue Date (excluding, for the avoidance of doubt, Liens securing any Additional Notes) and the related Guarantees;

(37) Liens on property or assets of any Non-Recourse Subsidiary under construction (and related rights) in favor of a contractor or developer or arising from progress or partial payments by a third party relating to such property or assets;

(38) Liens on vehicles or equipment of any Non-Recourse Subsidiary in the ordinary course of business or consistent with past practice or industry norms;

(39) Liens securing Indebtedness of Recourse Persons permitted under Section 4.09; provided that such Liens are secured by Collateral and junior in priority to the Liens securing the Notes;

(40) Liens on assets securing any Indebtedness owed to any Captive Insurance Subsidiary by the Issuer or any Restricted Subsidiary;

(41) Liens securing any Project Obligations, Permitted Project Undertakings or any Permitted Transactions;

(42) Liens existing, or deemed to exist, in connection with the sale or transfer of any assets in a transaction not prohibited under this Indenture, customary rights and restrictions contained in agreements relating to such sale or transfer pending the completion thereof; and

(43) Liens (i) on accounts receivable, royalty or other revenue streams and other rights to payment and any other assets incurred in connection with a Permitted Receivables Financing, (ii) in connection with bankers’ acceptances, discounted bills of exchange or the discounting or factoring of receivables for credit management purposes, in each case incurred or undertaken in the ordinary course of business, (iii) on Permitted Receivables Financing Assets or Liens on other assets granted pursuant to Standard Securitization Undertakings, in each case, incurred in connection with Permitted Receivables Financings permitted under this Indenture and (iv) securing Refinancing Indebtedness of the foregoing.

For purposes of this definition, the term “Indebtedness” shall be deemed to include interest on such Indebtedness. In the event that a Permitted Lien meets the criteria of more than one of the types of Permitted Liens (at the time of incurrence or at a later date), the Issuer in its sole discretion may divide, classify or from time to time reclassify all or any portion of such Permitted Lien in any manner that complies with this Indenture and such Permitted Lien shall be treated as having been made pursuant only to the clause or clauses of the definition of Permitted Lien to which such Permitted Lien has been classified or reclassified.

 

38


Permitted Project Undertaking” means, as to any Person, any guarantee or other credit support provided by such Person (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness), or any payment, performance or other obligation in respect of which such Person or is directly or indirectly liable (as a guaranteeing person or otherwise) or has granted a Lien on any of its assets as security (or has any obligation, contingent or otherwise, to do so), in each case, pursuant to any Project Obligation or otherwise arising in connection with any Project Document, any Project or any Permitted Business Investment (whether in favor or vendors, suppliers, contractors, customers, clients or otherwise), in each case excluding any Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations and debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit. For the avoidance of doubt, any guarantee to be issued by any Recourse Person in favor of Baker Hughes Energy Services LLC in respect of any Purchase Order for Liquefaction Train System equipment or for Power Island System equipment in connection with any Project shall be a “Permitted Project Undertaking.”

Permitted Receivables Financing” means any securitization or other similar financing (including any factoring program) of Permitted Receivables Financing Assets that is non-recourse to the Issuer and its Restricted Subsidiaries (except for any customary limited recourse pursuant to the Standard Securitization Undertakings), and in each case, reasonable extensions thereof.

Permitted Receivables Financing Assets” means (a) any accounts receivable, loan receivables, mortgage receivables, receivables or loans relating to the financing of insurance premiums, royalty, patent or other revenue streams and other rights to payment or related assets and the proceeds thereof and (b) all assets securing or related to any such receivable or asset, all contracts and contract rights, guarantees or other obligations in respect of any such receivable or asset, lockbox accounts and records with respect to any such receivable or assets and any other assets (including inventory and proceeds thereof) customarily transferred (or in respect of which security interests are customarily granted) together with receivables or assets in connection with a securitization, factoring or receivables financing or sale transaction.

Permitted Transactions” means any of the following: (a) any Equity Financing Transaction, (b) any ECR Transaction, and (c) any prepayment, redemption, purchase, repurchase, or defeasance of all or part of any Equity Interests issued in connection with (including any Stonepeak Equity Interests), or that are the subject of, any Equity Financing Transaction or ECR Transaction.

Permitted Transferees” means, with respect to any Person that is a natural Person (and any Permitted Transferee of such Person), (a) such Person’s Immediate Family Members and (b) such Person’s estate, heirs, legatees, distributees, executors and/or administrators upon the death of such Person, or any private foundation or fund that is controlled thereby, and any other Person who was an Affiliate of such Person upon the death of such Person and who, upon such death, directly or indirectly owned Equity Interests in the Issuer or any Parent Entity.

Person” means any individual, corporation, limited liability company, partnership, joint venture, association, joint-stock company, trust, unincorporated organization or other business entity or any government or any agency or political subdivision thereof.

 

39


Pledged Equity” means, with respect to the Issuer or any Guarantor, the shares of Capital Stock of any other Person in which the Issuer or such Guarantor, as applicable, has granted a security interest to the Collateral Agent, for the benefit of the Notes Parties, pursuant to the Security Agreement, together with any other shares, stock or partnership unit certificates, options or rights of any nature whatsoever in respect of such Capital Stock that may be issued or granted to, or held by, the Issuer or such Guarantor.

Preferred Equity” or “Preferred Stock” means any Equity Interest with preferential rights of payment of dividends or upon liquidation, dissolution, or winding up.

Private Placement Legend” means the legend set forth in Section 2.06(g)(1) to be placed on all Notes issued under this Indenture, except where otherwise permitted by the provisions of this Indenture.

Project” means each of the following:

(1) any individual natural gas liquefaction and export project, together with any other businesses or assets (other than any other separate natural gas liquefaction and export project) that are reasonably related, complementary, incidental, synergistic or ancillary to such project or are, in whole or in part, extensions, expansions or developments of any thereof, as determined by the Issuer in good faith; and

(2) any one or more assets, facilities or projects in the energy industry, including natural gas pipelines, natural gas shipping assets (including liquefied natural gas carriers, tugs and floating storage units), natural gas gathering and processing projects, upstream gas projects, re-gasification projects, carbon capture and sequestration projects, in each case, together with any other businesses or assets that are reasonably related, ancillary or similar to any of the foregoing or are, in whole or in part, extensions, expansions or developments of any thereof, as determined by the Issuer in good faith.

For the avoidance of doubt, an individual “Project” for purposes of this Indenture may include any one or more of the foregoing (either alone or in combination), in each case to the extent they are reasonably related, complementary, incidental, synergistic, ancillary or similar, and any extensions, expansions or developments of any thereof (as determined by the Issuer in good faith), and still be deemed to be an individual Project for purposes of this Indenture, except that an individual Project may not include more than one individual natural gas liquefaction and export project.

Project Company” means any Restricted Subsidiary of the Issuer that (i) is the owner, lessor and/or operator of (or is formed to own, lease or operate) any Project, (ii) is the lessee, borrower, issuer or seller (or is formed to be the lessee, borrower, issuer or seller) in respect of any financing transaction entered into in connection with any Project, including any Non-Recourse Financing, Equity Financing Transaction, ECR Transaction or Sale and Leaseback Transaction, (iii) develops or constructs (or is formed to develop or construct) any Project, (iv) engages in, conducts or facilitates (or is formed to engage in, conduct or facilitate) any activities reasonably related or ancillary any activities described in clauses (i), (ii) and (iii) of this definition, and/or (v) any combination of the foregoing, in each case as determined by the Issuer in good faith.

 

40


Project Costs” means any and all costs of evaluating, acquiring, leasing, designing, engineering, procuring, purchasing, developing, constructing and operating a Project, including all costs incurred in connection with preparing for and implementing, optioning, permitting, insuring, constructing, installing, commissioning, financing (including pursuant to any Non-Recourse Financing, Equity Financing Transaction, ECR Transaction or Sale and Leaseback Transaction, and including interest, dividends and other amounts incurred or payable with respect thereto during construction, debt service and other reserves and the cost of any associated letters of credit and other credit support or equity backstop arrangements), testing and starting-up (including costs relating to all equipment, materials, spare parts and labor), in each case, whether incurred before or after the final investment decision with respect to such Project.

Project Document” means each contract, agreement, instrument or other written undertaking entered into by a Project Company in connection with the engineering, procurement, construction, testing, commissioning, completion, insuring, operation, maintenance or repair of a Project.

Project Obligations” means as to any Person, any Contractual Obligation under any Project Document or otherwise entered into or arising in connection with any Project Document, any Project, or with respect to any Project Costs, in each case excluding any Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations and debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit.

QIB” means a “qualified institutional buyer” as defined in Rule 144A.

Rating Agency” means any of the following: (a) S&P Global Ratings, a division of S&P Global Inc. (“S&P”); (b) Moody’s Investors Service, Inc. (“Moody’s”); or (c) Fitch Ratings, Inc. (“Fitch”), and, in each case, their respective successors.

Rating Decline” means, with respect to any series of Notes and in connection with any Change of Control, the occurrence of:

(1) during the occurrence and continuance of any period in which such Notes have two or more (or, if only one of the following ratings agencies is at the applicable time providing a rating for such Notes, one) ratings equal to or greater than (x) Baa3 by Moody’s, (y) BBB- by S&P and (z) BBB- by Fitch (or, if all of such entities cease to provide such ratings, the equivalent rating from any other “nationally recognized statistical rating organization” registered with the Commission) (such period, an “Investment Grade Period”), a ratings downgrade which results in such Notes no longer having two (or, if only one of the preceding ratings agencies is at the time providing a rating for such Notes, one) such ratings of at least BBB- or Baa3, as applicable; or

(2) during any period which is not an Investment Grade Period, a ratings downgrade of such Notes by any two (or, if only one of the following ratings agencies is at the time providing a rating for such Notes, one) of (x) Moody’s, (y) S&P and (z) Fitch (or, if all of such entities cease to provide such ratings, the equivalent rating from any other “nationally recognized statistical rating organization” registered with the Commission);

 

41


provided, however, that in each case such downgrade occurs on, or within 90 days after the earlier of (a) such Change of Control, (b) the date of public notice of the occurrence of such Change of Control, or (c) public notice of the intention by the Issuer to effect such Change of Control (which period shall be extended so long as the rating of the Issuer is under publicly announced consideration for downgrade by any Rating Agency); and provided further, that a Rating Decline otherwise arising by virtue of a particular reduction in rating will not be deemed to have occurred in respect of a particular Change of Control (and thus will be disregarded in determining whether a Rating Decline has occurred for purposes of the definition of Change of Control Triggering Event) if the Rating Agencies making the reduction in rating do not announce or publicly confirm or inform the Issuer that the reduction was the result, in whole or in part, of any event or circumstance comprised of or arising as a result of, or in respect of, the applicable Change of Control (whether or not the applicable Change of Control has occurred at the time of the Rating Decline).

Receivables Subsidiary” means (i) any direct or indirect Subsidiary of any Restricted Subsidiary, whose organizational documents contain restrictions on its purpose and activities intended to preserve its separateness from such Restricted Subsidiary and/or one or more Subsidiaries of such Restricted Subsidiary, established in connection with a Permitted Receivables Financing and (ii) any Unrestricted Subsidiary involved in a Permitted Receivables Financing, which is not permitted by the terms of such Permitted Receivables Financing to guarantee the obligations under the Notes or provide Collateral.

Recourse Persons” means (a) the Issuer, (b) the Guarantors and (c) each other Restricted Subsidiary that is not a Non-Recourse Subsidiary.

Refinancing Indebtedness” means any Indebtedness that refinances any Indebtedness in compliance with Section 4.09; provided, however:

(1) such Refinancing Indebtedness has a stated maturity that is either: (i) no earlier than the stated maturity of the Indebtedness being refinanced; or (ii) after the final maturity date of each series of Notes then outstanding;

(2) such Refinancing Indebtedness has an average life at the time such Refinancing Indebtedness is incurred that is equal to or greater than the average life of the Indebtedness being refinanced;

(3) such Refinancing Indebtedness has an aggregate principal amount (or if issued with an original issue discount, an aggregate issue price) that is equal to or less than (i) the aggregate principal amount (or if incurred with original issue discount, the aggregate accreted value) then outstanding or committed under the Indebtedness being refinanced, plus (ii) an amount necessary to pay any fees and expenses (including original issue discount, upfront fees or similar fees) and premiums (including tender premiums) and accrued and unpaid interest, related to such modification, refinancing, refunding, extension, renewal or replacement;

(4) if the Indebtedness being refinanced is subordinated Indebtedness, such Refinancing Indebtedness has a final maturity date later than the final maturity date of each series of Notes then outstanding, and is subordinated in right of payment to the Notes on terms at least as favorable to the holders of Notes as those contained in the Indebtedness being refinanced; and

 

42


(5) if the Indebtedness being refinanced is a Non-Recourse Financing, such Refinancing Indebtedness is a Non-Recourse Financing incurred by one or more Non- Recourse Subsidiaries;

provided, however, that Refinancing Indebtedness shall not include Indebtedness of (i) the Issuer or a Restricted Subsidiary that refinances Indebtedness of an Unrestricted Subsidiary or a Joint Venture, (ii) the Issuer or a Guarantor that refinances Indebtedness of a Restricted Subsidiary that is not a Guarantor or (iii) a Recourse Person that refinances Indebtedness of a Non-Recourse Subsidiary.

Regulation S” means Regulation S promulgated under the Securities Act.

Regulation S Global Note” means a Regulation S Temporary Global Note or Regulation S Permanent Global Note, as appropriate.

Regulation S Permanent Global Note” means a permanent Global Note, substantially in the form of Exhibit A-1 or Exhibit A-2 hereto bearing the Global Note Legend and the Private Placement Legend and deposited with or on behalf of, and registered in the name of, the Depositary or its nominee, issued in a denomination equal to the outstanding principal amount of the Regulation S Temporary Global Note upon expiration of the applicable Restricted Period.

Regulation S Temporary Global Note” means a temporary Global Note, substantially in the form of Exhibit A-1 or Exhibit A-2 hereto bearing the Global Note Legend and the Private Placement Legend and the Regulation S Temporary Global Note Legend and deposited with or on behalf of, and registered in the name of, the Depositary or its nominee, issued in a denomination equal to the outstanding principal amount of the Notes initially sold in reliance on Rule 903.

Regulation S Temporary Global Note Legend” means the legend set forth in Section 2.06(g)(3) hereof.

Reporting Default” means the failure by the Issuer or any Guarantor to comply with Section 4.03.

Responsible Officer,” when used with respect to the Trustee, means any officer within the Corporate Trust Administration of the Trustee (or any successor group of the Trustee) or any other officer of the Trustee customarily performing functions similar to those performed by any of the above designated officers and also means, with respect to a particular corporate trust matter, any other officer to whom such matter is referred because of his knowledge of and familiarity with the particular subject.

Restricted Definitive Note” means a Definitive Note bearing, or that is required to bear, the Private Placement Legend.

Restricted Global Note” means a Global Note bearing, or that is required to bear, the Private Placement Legend.

Restricted Investment” means any Investment other than a Permitted Investment.

 

43


Restricted Period” means the 40-day distribution compliance period as defined in Regulation S.

Restricted Subsidiary” means any Subsidiary of the Issuer that is not an Unrestricted Subsidiary.

Retained Asset Sale Proceeds” means, at any date of determination, an amount determined on a cumulative basis of all Net Proceeds received by the Issuer or any of its Restricted Subsidiaries that, pursuant to application of the Asset Sale Prepayment Percentage, are or were not required to be applied pursuant to Section 4.10.

Rule 144” means Rule 144 promulgated under the Securities Act.

Rule 144A” means Rule 144A promulgated under the Securities Act.

Rule 144A Global Note” means a Global Note issued in accordance with Section 2.01(c).

Rule 903” means Rule 903 promulgated under the Securities Act.

Rule 904” means Rule 904 promulgated under the Securities Act.

Sale and Leaseback Transaction” means any arrangement providing for the leasing by the Issuer or any Restricted Subsidiaries of any real or tangible personal property, which property has been or is to be sold or transferred by the Issuer or such Restricted Subsidiary to a third Person in contemplation of such leasing.

Screened Affiliate” means any Affiliate of a Holder (i) that makes investment decisions independently from such Holder and any other Affiliate of such Holder that is not a Screened Affiliate, (ii) that has in place customary information screens between it and such Holder and any other Affiliate of such Holder that is not a Screened Affiliate and such screens prohibit the sharing of information with respect to the Issuer or its Subsidiaries, (iii) whose investment policies are not directed by such Holder or any other Affiliate of such Holder that is acting in concert with such Holder in connection with its investment in the Notes, and (iv) whose investment decisions are not influenced by the investment decisions of such Holder or any other Affiliate of such Holder that is acting in concert with such Holders in connection with its investment in the Notes.

Securities Act” means the Securities Act of 1933, as amended.

Security Agreement” means the Security Agreement to be entered into on the Issue Date among the Issuer, each other Grantor (as defined and referred to therein) and the Collateral Agent, as it may be amended, amended and restated, supplemented or otherwise modified from time to time.

Security Documents” means:

(1) the Security Agreement;

(2) the Collateral Agency Agreement;

 

44


(3) the Applicable Intercreditor Agreements, if any; and

(4) each of the security agreements, financing statements and other instruments executed and delivered by the Issuer or any Guarantor pursuant to this Indenture for purposes of providing collateral security or credit support for the Note Obligation;

as the same may be amended, amended and restated, supplemented or otherwise modified or replaced from time to time.

Senior Class Debt Representative” means, with respect to this Indenture, the Trustee, and with respect to any Additional First Lien Debt Facility, the applicable Additional Agent that becomes a party to an Applicable Intercreditor Agreement.

Senior Indebtedness” means: (a) any Indebtedness of the Issuer that ranks equally in right of payment with the Notes; and (b) any Indebtedness of a Guarantor that ranks equally in right of payment to the Guarantee of such Guarantor.

series” means (a) with respect to the Notes, each of (i) the 2028 Notes and (ii) the 2031 Notes, and (b) with respect to any First Lien Obligations, each of (i) the Note Obligations with respect to the 2028 Notes, (ii) the Note Obligations with respect to the 2031 Notes and (iii) the Additional First Lien Obligations incurred pursuant to any Additional First Lien Debt Facility or any related Additional First Lien Documents.

Short Derivative Instruments” means, as to any person, a Derivative Instrument (i) the value of which to such person generally decreases, and/or the payment or delivery obligations of such person under which generally increase, with positive changes in the financial performance and/or position of the Issuer and/or (ii) the value of which to such person generally increases, and/or the payment or delivery obligations of such person under which generally decrease, with negative changes in the financial performance and/or position of the Issuer.

Standard Securitization Undertakings” means all representations, warranties, covenants, pledges, transfers, purchases, dispositions, guaranties and indemnities (including repurchase obligations in the event of a breach of representation and warranty) and other undertakings made or provided, and servicing obligations undertaken, by any Restricted Subsidiary or Subsidiary thereof that the Issuer has determined in good faith to be customary in connection with a Permitted Receivables Financing.

Stated Maturity” means, with respect to any installment of interest or principal on any series of Indebtedness, the date on which the payment of interest or principal was scheduled to be paid in the documentation governing such Indebtedness as of the date of this Indenture, and will not include any contingent obligations to repay, redeem or repurchase any such interest or principal prior to the date originally scheduled for the payment thereof.

Stonepeak Equity Interests” means the Equity Interests of Calcasieu Pass Holdings, LLC and Calcasieu Pass Funding, LLC owned by Stonepeak Bayou Holdings LP and Stonepeak Bayou Holdings II LP, respectively.

 

45


Subsidiary” means, with respect to any specified Person:

(1) any corporation, association or other business entity of which more than 50% of the total voting power of shares of Capital Stock entitled (without regard to the occurrence of any contingency and after giving effect to any voting agreement or stockholders’ agreement that effectively transfers voting power) to vote in the election of directors, managers or trustees of the corporation, association or other business entity is at the time owned or controlled, directly or indirectly, by that Person or one or more of the other Subsidiaries of that Person (or a combination thereof);

(2) any partnership, joint venture, limited liability company or similar entity of which: more than 50% of the capital accounts, distribution rights, total equity and voting interests or general or limited partnership interests, as applicable, are owned or controlled, directly or indirectly, by such Person or one or more of the other Subsidiaries of that Person (or a combination thereof) whether in the form of membership, general, special or limited partnership or otherwise, and such Person or any Restricted Subsidiary of such Person is a controlling general partner or otherwise controls such entity; and

(3) any other entity, the management of which is controlled, directly or indirectly (whether by way of equity ownership or contractual arrangements or otherwise), by that Person or one or more of the other Subsidiaries of that Person (or a combination thereof) and the accounts of which would be consolidated with those of the Issuer in its consolidated financial statements as of such date prepared in accordance with GAAP.

Unless otherwise specified herein, a “Subsidiary” shall refer to a Subsidiary of the Issuer.

Tax” means all present or future taxes, levies, imposts, duties, assessments, charges, fees, deductions or withholdings (together with interest, penalties and other additions thereto) of any nature and whatever called, by whomsoever, on whomsoever and wherever imposed, levied, collected, withheld or assessed.

Tax Restructuring” means any reorganizations and other activities related to tax planning and tax reorganization (as determined by the Issuer in good faith) entered into after the Issue Date so long as such Tax Restructuring does not (1) materially impair (i) the ability of the Issuer and the Guarantors to make anticipated principal or interest payments on the Notes, (ii) any Guarantees or (iii) the security interests of the Collateral Agent on behalf of holders of the Notes, in each case, taken as a whole, or (2) cause material adverse Tax consequences to the holders of the Notes.

Test Period” means, with respect to any date of determination, the most recently ended four full consecutive fiscal quarters of the Issuer for which internal financial statements are available.

Test Revenue” means, for any period, the aggregate amount of net proceeds received by the Issuer and its Restricted Subsidiaries from sales generated by assets of any Project or Permitted Business prior to such assets being placed in service for accounting purposes in accordance with GAAP, and that are recognized as an offset to construction in progress on the balance sheet of the Issuer, determined on a consolidated basis in accordance with GAAP.

TIA” means the Trust Indenture Act of 1939, as amended (15 U.S.C. §§ 77aaa-77bbbb).

 

46


Treasury Rate” means, as of any redemption date, the yield to maturity as of the earlier of (a) such redemption date or (b) the date on which the Notes are defeased or satisfied and discharged, of United States Treasury securities with a constant maturity (as compiled and published in the most recent Federal Reserve Statistical Release H.15 (519) that has become publicly available at least two Business Days prior to the redemption date (or, if such Statistical Release is no longer published, any publicly available source of similar market data)) most nearly equal to the period from the redemption date to, with respect to the 2028 Notes, June 1, 2025, and, with respect to the 2031 Notes, June 1, 2026; provided, however, that if such period is less than one year, the weekly average yield on actively traded United States Treasury securities adjusted to a constant maturity of one year will be used.

Trustee” means The Bank of New York Mellon Trust Company, N.A. until a successor replaces it in accordance with the applicable provisions of this Indenture and thereafter means the successor serving hereunder.

UCC” means the Uniform Commercial Code as in effect from time to time in any applicable jurisdiction.

Unrestricted Definitive Note” means a Definitive Note that does not bear and is not required to bear the Private Placement Legend.

Unrestricted Global Note” means a Global Note that does not bear and is not required to bear the Private Placement Legend.

Unrestricted Subsidiary” means:

(1) any Subsidiary of the Issuer that at the time of determination is an Unrestricted Subsidiary (as designated by the Board of Directors of the Issuer in accordance with Section 4.17);

(2) any Subsidiary of an Unrestricted Subsidiary; and

(3) as of the Issue Date, includes VG LNG Marketing, LLC, VG LNG Marketing Pte. Ltd., CPCD, LLC, Venture Global Controls, LLC, VG Aviation, LLC, Bayou Residential, LLC, and SQRD Holding LLC.

“U.S. dollars” or “$” means the lawful currency of the United States of America.

“U.S. Person” means a U.S. Person as defined in Rule 902(k) promulgated under the Securities Act.

VGP Investor” means, collectively, (a) Venture Global Partners, LLC and its Affiliates and (b) the funds, partnerships or other co-investment vehicles managed, advised or controlled by any Person referred to in the foregoing clause (a).

 

47


Voting Stock” of any specified Person as of any date means the Capital Stock of such Person that is at that time entitled to vote in the election of the Board of Directors (or comparable governing body) of such Person, measured by voting power rather than number of shares. For the avoidance of doubt, the sole managing member of a sole-member-managed limited liability company owns 100% of the Voting Stock of such limited liability company and the sole general partner of a limited partnership owns 100% of the Voting Stock of the limited partnership.

Wholly-Owned Subsidiary” means, with respect to any specified Person, a direct or indirect Subsidiary of such Person, 100% of the outstanding Capital Stock or other ownership interests of which (other than directors’ qualifying shares) is at the time owned by such Person or by one or more Wholly-Owned Subsidiaries of such Person.

Section 1.02 Other Definitions.

 

Term

  

Defined in

Section

Advance Offer    4.10(d)
Advance Portion    4.10(d)
Affiliate Transaction    4.11(a)
Applicable Tax Laws    13.12
Asset Sale Offer    4.10(d)
Authentication Order    2.02
Change of Control Offer    4.15(a)
Change of Control Payment    4.15(b)
Change of Control Payment Date    4.15(b)
Collateral Advance Offer    4.10(c)
Collateral Advance Portion    4.10(c)
Collateral Asset Sale Offer    4.10(c)
Collateral Excess Proceeds    4.10(c)
Court Determination    6.02
Covenant Defeasance    8.03
Covenant Suspension Event    4.18(b)
Declined Collateral Excess Proceeds    4.10(c)
Declined Excess Proceeds    4.10(d)
Declined Non-Collateral Excess Proceeds    4.10(d)
Directing Holder    6.02
DTC    2.03
Event of Default    6.01
Excess Proceeds    4.10(d)
First Lien Intercreditor Agreement    12.02(e)
Guarantee Date    4.16
Increased Amount    4.12
Incremental Funds    4.07(a)
Initial Default    6.02

 

48


Term

   Defined in
Section
incur    4.09(a)
Instructing Officers    7.02(m)
Instructions    7.02(m)
Legal Defeasance    8.02
Noteholder Direction    6.02
Notes Offer    4.10(b)(1)(A)
Offer Amount    3.09(b)
Offer Period    3.09(b)
Paying Agent    2.03
Permitted Debt    4.09(b)
Position Representation    6.02
Purchase Date    3.09(b)
Registrar    2.03
Restricted Payments    4.07
Reversion Date    4.18(b)
Senior Lien Intercreditor Agreement    12.02(d)
Subject Lien    4.12
Suspended Covenants    4.18(b)
Transaction Election    1.04
Transaction Test Date    1.04
Verification Covenant    6.02

Section 1.03 Rules of Construction.

(a) Unless the context otherwise requires:

(1) the table of contents and headings are for convenience only and shall not affect the interpretation of this Indenture;

(2) unless otherwise specified, references to articles, sections, clauses, appendices, exhibits, schedules or annexes are references to articles, sections, clauses, appendices, exhibits, schedules or annexes to this Indenture;

(3) references to any party to this Indenture or any other document or agreement shall include its successors and permitted transferees and assigns;

(4) an “authorization” includes an authorization, consent, approval, resolution, license, exemption, filing, registration and notarization;

 

49


(5) “law” shall be construed as any law (including common or customary law), statute, constitution, decree, judgment, treaty, regulation, directive, by-law, order, ordinance or any other legislative measure of any government, supranational, local government, statutory or regulatory body or court, in each case having the force of law;

(6) unless as otherwise provided, any reference to assignment of a person’s rights and/or obligations shall be construed to refer to assignment, transfer or novation of those rights and/or obligations;

(7) any reference to the actions or omissions of agents, representatives or authorized persons shall refer only to actions or omissions taken in connection with the agency, representation or authorization;

(8) the omission of the word “any” or the phrase “if any” with respect to anything shall not imply that the thing exists or is required, notwithstanding the inclusion of such word or phrase (for clarity) in other provisions;

(9) any reference to an action being taken “pursuant to” an agreement or document, or any specified provision thereof, shall be construed to mean “pursuant to and in compliance with” the requirements of such agreement, document or provision;

(10) in some instances, a word or reference that, pursuant to these rules of interpretation, is not necessary (for example, inclusion of both the singular and plural), may be included for emphasis or clarity, and any such usage shall not give rise to any negative implication in relation to any other usage, which other usage shall nonetheless be interpreted strictly in accordance with the rules of interpretation set forth herein;

(11) a term has the meaning assigned to it;

(12) an accounting term not otherwise defined has the meaning assigned to it in accordance with GAAP;

(13) “or” is not exclusive;

(14) “including” means “including without limitation” whether or not stated;

(15) words in the singular include the plural, and in the plural include the singular;

(16) “will” shall be interpreted to express a command and shall be construed to have the same meaning and effect as the word “shall”;

(17) provisions apply to successive events and transactions;

(18) references to sections of or rules under the Securities Act will be deemed to include substitute, replacement of successor sections or rules adopted by the Commission from time to time; and

 

50


(19) references to any document, agreement or instrument means such document, agreement or instrument as it may be amended, amended and restated or otherwise modified in accordance with its terms.

Section 1.04  Limited Condition Transactions. Notwithstanding anything in this Indenture to the contrary, when (i) calculating availability under any applicable basket or ratio in this Indenture in connection with the incurrence of Indebtedness, the creation of Liens, the making of any Asset Sale, the making of any acquisitions, the making of an Investment, the making of a Restricted Payment, the designation of a Subsidiary as restricted or unrestricted, the repayment of Indebtedness or for any other purpose, (ii) determining whether any Default or Event of Default has occurred, is continuing or would result from any action, or (iii) determining compliance with any representations and warranties and any other condition precedent to any action or transaction, in each case of clauses (i) through (iii) in connection with a Limited Condition Transaction, the date of determination of such basket or ratio, whether any Default or Event of Default has occurred, is continuing or would result therefrom, or the satisfaction of any other condition precedent shall, at the option of the Issuer (the Issuer’s election to exercise such option in connection with any Limited Condition Transaction, a “Transaction Election”), be deemed to be the date of declaration of such Restricted Payment or the date that the definitive agreement for such Restricted Payment, Investment, acquisition, Asset Sale or incurrence, repayment, repurchase or refinancing of Indebtedness, Disqualified Stock or Preferred Equity is entered into, the date a public announcement of an intention to make an offer in respect of the target of such acquisition or Investment or the date of such notice, which may be conditional, of such repayment, repurchase or refinancing of Indebtedness, Disqualified Stock or Preferred Equity or such Asset Sale is given to the holders of such Indebtedness, Disqualified Stock or Preferred Equity (any such date, the “Transaction Test Date”). If on a pro forma basis after giving effect to such Limited Condition Transaction and the other transactions to be entered into in connection therewith (including any acquisitions, Investments, the incurrence or issuance of Indebtedness, Disqualified Stock or Preferred Stock and the use of proceeds thereof, the incurrence of Liens, repayments, Restricted Payments and Asset Sales) and any related pro forma adjustments, with such baskets and ratios, absence of defaults, satisfaction of conditions precedent and other provisions calculated as if such Limited Condition Transaction or other transactions had occurred on the relevant Transaction Test Date in compliance with the applicable baskets and ratios or other provisions, such provisions shall be deemed to have been complied with. For the avoidance of doubt, (i) if any of such baskets, ratios, absence of defaults, satisfaction of conditions precedent or other provisions are exceeded or breached as a result of fluctuations in such ratio (including due to fluctuations in Distributable Cash), a change in facts and circumstances or other provisions at or prior to the consummation of the relevant Limited Condition Transaction, such ratios, absence of defaults, satisfaction of conditions precedent and other provisions will not be deemed to have been exceeded, breached, or otherwise failed to have been satisfied as a result of such fluctuations or changed circumstances solely for purposes of determining whether the Limited Condition Transaction and any related transactions is permitted hereunder and (ii) such baskets and ratios and compliance with such conditions shall not be tested at the time of consummation of such Limited Condition Transaction or related transactions. If the Issuer has made a Transaction Election for any Limited Condition Transaction, then in connection with any subsequent calculation of any ratio or basket availability with respect to any other Limited Condition Transaction or otherwise on or following the relevant Transaction Test Date and prior to the earlier of the date on which such Limited Condition Transaction is consummated or the date that the definitive agreement for such Limited Condition

 

51


Transaction is terminated or expires without consummation of such Limited Condition Transaction, any such ratio or basket shall be calculated on a pro forma basis assuming such Limited Condition Transaction and other transactions in connection therewith (including any incurrence of Indebtedness and the use of proceeds thereof) have been consummated. For purposes of any calculation of any ratio that includes Fixed Charges or otherwise includes interest expense of any Indebtedness to be incurred, such Fixed Charges or interest expense may be calculated using an assumed interest rate for the Indebtedness to be incurred in connection with such Limited Condition Transaction based on the indicative interest margin contained in any financing commitment documentation with respect to such Indebtedness or, if no such indicative interest margin exists, as reasonably determined by the Issuer in good faith.

Section 1.05 Certain Compliance Calculations.

(a) Notwithstanding anything to the contrary herein, in the event an item of Indebtedness, Disqualified Stock or Preferred Equity (or any portion thereof) is incurred or issued, any Lien is incurred or other transaction is undertaken based on a ratio basket based on the Holdco Debt Ratio, such ratio(s) shall be calculated with respect to such incurrence, issuance or other transaction without giving effect to (a) amounts being utilized under any other basket (other than a ratio basket based on the Holdco Debt Ratio) on the same date, or (b) the incurrence of any Indebtedness under any revolving facility or letter of credit facility immediately prior to or in connection therewith. Each item of Indebtedness, Disqualified Stock or Preferred Equity that is incurred or issued, each Lien incurred and each other transaction undertaken will be deemed to have been incurred, issued or taken first, to the extent available, pursuant to the Holdco Debt Ratio test.

(b) For purposes of any calculation under this Indenture, the Issuer may elect, at any time (which election may not be changed with respect to such revolving Indebtedness), to either (x) give pro forma effect to the incurrence of the entire committed amount of such revolving Indebtedness, in which case such committed amount may thereafter be borrowed or reborrowed, in whole or in part, from time to time, without further compliance with any provision under this Indenture, or (y) give pro forma effect to the incurrence of the actual amount drawn under such revolving Indebtedness, in which case, the ability to incur the amounts committed to under such revolving Indebtedness will be subject to the provisions of this Indenture.

Section 1.06 Acts of Holders.

(a) Any request, demand, authorization, direction, notice, consent, waiver or other action provided by this Indenture to be given or taken by Holders may be embodied in and evidenced by one or more instruments of substantially similar tenor signed by such Holders in person or by an agent duly appointed in writing. Except as herein otherwise expressly provided, such action shall become effective when such instrument or instruments are delivered to the Trustee and, where it is hereby expressly required, to the Issuer. Proof of execution of any such instrument or of a writing appointing any such agent, or the holding by any Person of a Note, shall be sufficient for any purpose of this Indenture and (subject to Section 7.01 hereof) conclusive in favor of the Trustee and the Issuer, if made in the manner provided in this Section 1.06.

 

52


(b) The fact and date of the execution by any Person of any such instrument or writing may be proved by the affidavit of a witness of such execution or by the certificate of any notary public or other officer authorized by law to take acknowledgments of deeds, certifying that the individual signing such instrument or writing acknowledged to him the execution thereof. Where such execution is by or on behalf of any legal entity other than an individual, such certificate or affidavit shall also constitute proof of the authority of the Person executing the same. The fact and date of the execution of any such instrument or writing, or the authority of the Person executing the same, may also be proved in any other manner that the Trustee deems sufficient.

(c) Any request, demand, authorization, direction, notice, consent, waiver or other action by the Holder of any Note shall bind every future Holder of the same Note and the Holder of every Note issued upon the registration of transfer thereof or in exchange therefor or in lieu thereof, in respect of any action taken, suffered or omitted by the Trustee or the Issuer in reliance thereon, whether or not notation of such action is made upon such Note.

(d) The Issuer may set a record date for purposes of determining the identity of Holders entitled to give any request, demand, authorization, direction, notice, consent, waiver or take any other act, or to vote or consent to any action by vote or consent authorized or permitted to be given or taken by Holders. Unless otherwise specified, if not set by the Issuer prior to the first solicitation of a Holder made by any Person in respect of any such action, or in the case of any such vote, prior to such vote, any such record date shall be the later of 10 days prior to the first solicitation of such consent or the date of the most recent list of Holders furnished to the Trustee prior to such solicitation.

(e) Without limiting the foregoing, a Holder entitled to take any action hereunder with regard to any particular Note may do so with regard to all or any part of the principal amount of such Note or by one or more duly appointed agents, each of which may do so pursuant to such appointment with regard to all or any part of such principal amount. Any notice given or action taken by a Holder or its agents with regard to different parts of such principal amount pursuant to this Section 1.06(e) shall have the same effect as if given or taken by separate Holders of each such different part.

(f) Without limiting the generality of the foregoing, a Holder, including DTC and the Depositary, that is a Holder of a Global Note may make, give or take, by a proxy or proxies duly appointed in writing, any request, demand, authorization, direction, notice, consent, waiver or other action provided in this Indenture to be made, given or taken by Holders, and any Person that is a Holder of a Global Note, including DTC and the Depositary, may provide its proxy or proxies to the beneficial owners of interests in any such Global Note through such Depositary’s standing instructions and customary practices.

(g) The Issuer may fix a record date for the purpose of determining the Persons who are beneficial owners of interests in any Global Note held by DTC entitled under the procedures of such Depositary to make, give or take, by a proxy or proxies duly appointed in writing, any request, demand, authorization, direction, notice, consent, waiver or other action provided in this Indenture to be made, given or taken by Holders. If such a record date is fixed, the Holders on such record date or their duly appointed proxy or proxies, and only such Persons, shall be entitled to make, give or take such request, demand, authorization, direction, notice, consent, waiver or other action, whether or not such Holders remain Holders after such record date. No such request, demand, authorization, direction, notice, consent, waiver or other action shall be valid or effective if made, given or taken more than 120 days after such record date.

 

53


Section 1.07 Timing of Payment. Notwithstanding anything herein to the contrary, if the date on which any payment is to be made pursuant to this Indenture or the Notes is not a Business Day, the payment otherwise payable on such date shall be payable on the next succeeding Business Day with the same force and effect as if made on such scheduled date and (provided such payment is made on such succeeding Business Day) no interest shall accrue on the amount of such payment from and after such scheduled date to the time of such payment on such next succeeding Business Day and the amount of any such payment that is an interest payment will reflect accrual only through the original payment date and not through the next succeeding Business Day.

Section 1.08 Role of the Collateral Agent. The parties hereto agree that, in acting hereunder, the Collateral Agent shall be entitled to all of its rights, powers, protections and immunities set forth in the Collateral Agency Agreement (and that, in the case of any conflict between the provisions of this Indenture and the provisions of the Collateral Agency Agreement in respect of such rights, powers, protections and immunities only, the Collateral Agency Agreement shall prevail).

ARTICLE 2

THE NOTES

Section 2.01 Form and Dating.

(a) General. The Notes shall be in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The terms and provisions contained in the Notes will constitute, and are hereby expressly made, a part of this Indenture and the Issuer, the Guarantors and the Trustee, by their execution and delivery of this Indenture, expressly agree to such terms and provisions and to be bound thereby. However, to the extent any provision of any Note conflicts with the express provisions of this Indenture, the provisions of this Indenture shall govern and be controlling.

(b) Global Notes. Except as otherwise provided in this Section 2.01, Notes issued in global form (and the Trustee’s certificate of authentication of such Notes) will be substantially in the form of Exhibit A-1 or A-2 (including the Global Note Legend thereon and the “Schedule of Exchanges of Interests in the Global Note” attached thereto). Each such Note will be dated the date of its authentication. Except as otherwise provided in this Section 2.01, Notes issued in definitive form will be substantially in the form of Exhibit A-1 or A-2 (but without the Global Note Legend thereon and without the “Schedule of Exchanges of Interests in the Global Note” attached thereto). Each Global Note will represent such of the outstanding Notes as will be specified therein and each shall provide that it represents the aggregate principal amount of outstanding Notes from time to time endorsed thereon and that the aggregate principal amount of outstanding Notes represented thereby may from time to time be reduced or increased, as appropriate, to reflect exchanges and redemptions. Any endorsement of a Global Note to reflect the amount of any increase or decrease in the aggregate principal amount of outstanding Notes represented thereby will be made by the Trustee or the Custodian, at the direction of the Trustee, in accordance with instructions given by the Holder thereof as required by Section 2.06.

 

54


(c) Temporary Global Notes. Notes offered and sold in reliance on Regulation S shall be issued initially in the form of the Regulation S Temporary Global Notes duly executed by the Issuer and authenticated by the Trustee as hereinafter provided.

Following the termination of the applicable Restricted Period, the Regulation S Temporary Global Note Legend shall be deemed removed from the Regulation S Temporary Global Note for the Notes, following which temporary beneficial interests in the Regulation S Temporary Global Note shall automatically become beneficial interests in the Regulation S Permanent Global Note of the Notes pursuant to the Applicable Procedures.

The aggregate principal amount of a Regulation S Temporary Global Note for the Notes and a Regulation S Permanent Global Note of the Notes may from time to time be increased or decreased by adjustments made on the records of the Trustee and/or the Paying Agent and the Depositary or their respective nominees, as the case may be, in connection with transfers of interest as hereinafter provided.

(d) Euroclear and Clearstream Procedures Applicable. The provisions of the “Operating Procedures of the Euroclear System” and “Terms and Conditions Governing Use of Euroclear” and the “General Terms and Conditions of Clearstream Banking” and “Customer Handbook” of Clearstream will be applicable to transfers of beneficial interests in the Regulation S Temporary Global Note and the Regulation S Permanent Global Note that are held by Participants through Euroclear or Clearstream.

(e) Additional Notes. Subject to compliance with the provisions of this Indenture, the Issuer may, without notice to or the consent of the Holders from time to time after the Issue Date issue Additional Notes, in addition to the Initial Additional Notes to be issued on the Issue Date, ranking pari passu with the Initial Notes, and such Additional Notes shall be consolidated with and form a single class with the Initial Notes (except as otherwise provided for herein) and shall have the same terms as the Initial Notes (except for any differences in the issue price, the issue date and the interest accrued, if any); provided, however, that a separate CUSIP or ISIN will be issued for the Additional Notes, unless the Additional Notes are fungible with the Initial for U.S. federal income tax purposes. Any Additional Notes shall be issued with the benefit of an indenture supplemental to this Indenture.

Section 2.02 Execution and Authentication.

At least one Officer must sign the Notes for the Issuer by manual or electronic signature.

If an Officer whose signature is on a Note no longer holds that office at the time a Note is authenticated, the Note will nevertheless be valid.

A Note will not be valid until authenticated by the manual or electronic signature of the Trustee. The signature will be conclusive evidence that the Note has been authenticated under this Indenture.

 

55


At any time and from time to time after the execution and delivery of this Indenture, the Issuer may deliver Notes executed by the Company to the Trustee for authentication, together with a written order of the Issuer signed by at least one Officer for the authentication and delivery of such Notes (an “Authentication Order”), and the Trustee in accordance with such Authentication Order shall authenticate and deliver such Notes, without any further action by the Issuer hereunder; provided that the Trustee shall be entitled to receive an Officer’s Certificate and an Opinion of Counsel with respect to the issuance, authentication and delivery of any Additional Notes. The aggregate principal amount of Notes outstanding at any time may not exceed the aggregate principal amount of Notes authorized for issuance by the Issuer pursuant to one or more Authentication Orders, except as provided in Section 2.07.

The Trustee may appoint an authenticating agent acceptable to the Issuer to authenticate Notes. An authenticating agent may authenticate Notes whenever the Trustee may do so. Each reference in this Indenture to authentication by the Trustee includes authentication by such agent. An authenticating agent has the same rights as an Agent to deal with Holders or an Affiliate of the Issuer.

For the avoidance of any doubt, any Additional Notes that are issued in connection with a transaction in which an Officer’s Certificate and Opinion of Counsel was delivered shall be valid for all purposes and constitute Additional Notes hereunder, even if subsequently it is determined that such issuance was not in compliance with the covenants of this Indenture.

Section 2.03 Registrar and Paying Agent.

The Issuer will maintain an office or agency where Notes may be presented for registration of transfer or for exchange (“Registrar”) and an office or agency where Notes may be presented for payment (“Paying Agent”). The Registrar will keep a register of the Notes and of their transfer and exchange. The Issuer may appoint one or more co-registrars and one or more additional paying agents. The term “Registrar” includes any co-registrar and the term “Paying Agent” includes any additional paying agent. The Issuer may change any Paying Agent or Registrar without notice to any Holder. The Issuer will notify the Trustee in writing of the name and address of any Agent not a party to this Indenture. If the Issuer fails to appoint or maintain another entity as Registrar or Paying Agent, the Trustee shall act as such. The Issuer or any of its Subsidiaries may act as Paying Agent or Registrar.

The Issuer initially appoints The Depository Trust Company (“DTC”) to act as Depositary with respect to the Global Notes.

The Issuer initially appoints the Trustee to act as the Registrar and Paying Agent and to act as Custodian with respect to the Global Notes.

Section 2.04 Paying Agent to Hold Money in Trust.

The Issuer will require each Paying Agent other than the Trustee to agree in writing that the Paying Agent will hold in trust for the benefit of Holders or the Trustee all money held by the Paying Agent for the payment of principal, premium, or interest on the Notes, and will notify the Trustee of any default by the Issuer in making any such payment. While any such default continues, the Trustee may require a Paying Agent to pay all money held by it to the Trustee. The Issuer at

 

56


any time may require a Paying Agent to pay all money held by it to the Trustee. Upon payment over to the Trustee, the Paying Agent (if other than the Issuer or a Subsidiary) will have no further liability for the money. If the Issuer or a Subsidiary acts as Paying Agent, it will segregate and hold in a separate trust fund for the benefit of the Holders all money held by it as Paying Agent. Upon any bankruptcy or reorganization proceedings relating to the Issuer, the Trustee will serve as Paying Agent for the Notes.

Section 2.05 Holder Lists.

The Trustee will preserve in as current a form as is reasonably practicable the most recent list available to it of the names and addresses of all Holders. If the Trustee is not the Registrar, the Issuer on its own behalf and on behalf of the Guarantors will furnish to the Trustee at least seven Business Days before each Interest Payment Date and at such other times as the Trustee may request in writing, a list in such form and as of such date as the Trustee may reasonably require of the names and addresses of the Holders.

Section 2.06 Transfer and Exchange.

(a) Transfer and Exchange of Global Notes. A Global Note may not be transferred except as a whole by the Depositary to a nominee of the Depositary, by a nominee of the Depositary to the Depositary or to another nominee of the Depositary, or by the Depositary or any such nominee to a successor Depositary or a nominee of such successor Depositary. All Global Notes will be exchanged by the Issuer for Definitive Notes if:

(1) the Depositary notifies the Issuer that it is unwilling or unable to continue to act as Depositary for the Global Notes or that it has ceased to be a clearing agency registered under the Exchange Act and, in either case, a successor Depositary is not appointed by the Issuer within 120 days after the date of such notice from the Depositary;

(2) the Issuer, at its option, notifies the Trustee in writing that it elects to cause this issuance of Definitive Notes; provided that in no event shall the Regulation S Temporary Global Note be exchanged by the Issuer for Definitive Notes prior to (A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903(b)(3)(ii)(B) under the Securities Act; or

(3) there has occurred and is continuing an Event of Default with respect to the Notes.

Upon the occurrence of any of the preceding events, Definitive Notes shall be issued and delivered in such names as the Depositary shall instruct the Trustee, in accordance with the Depositary’s customary procedures. Global Notes also may be exchanged or replaced, in whole or in part, as provided in Section 2.07 and Section 2.10. Every Note authenticated and delivered in exchange for, or in lieu of, a Global Note or any portion thereof, pursuant to this Section Section 2.06 or Section 2.07 or Section 2.10, shall be authenticated and delivered in the form of, and shall be, a Global Note. A Global Note may not be exchanged for another Note other than as provided in this Section 2.06(a), however, beneficial interests in a Global Note may be transferred and exchanged as provided in Section 2.06(b) or (c).

 

57


(b) Transfer and Exchange of Beneficial Interests in the Global Notes. The transfer and exchange of beneficial interests in the Global Notes will be effected through the Depositary, in accordance with the provisions of this Indenture and the Applicable Procedures. Beneficial interests in the Restricted Global Notes will be subject to restrictions on transfer comparable to those set forth herein to the extent required by the Securities Act. Transfers of beneficial interests in the Global Notes also will require compliance with either subparagraph (1) or (2) below, as applicable, as well as one or more of the other following subparagraphs, as applicable:

(1) Transfer of Beneficial Interests in the Same Global Note. Beneficial interests in any Restricted Global Note may be transferred to Persons who take delivery thereof in the form of a beneficial interest in the same Restricted Global Note in accordance with the transfer restrictions set forth in the Private Placement Legend; provided, however, that prior to the expiration of the Restricted Period, transfers of beneficial interests in the Regulation S Temporary Global Note may not be made to a U.S. Person or for the account or benefit of a U.S. Person (other than the Initial Purchasers). Beneficial interests in any Unrestricted Global Note may be transferred to Persons who take delivery thereof in the form of a beneficial interest in an Unrestricted Global Note. No written orders or instructions shall be required to be delivered to the Registrar to effect the transfers described in this Section 2.06(b)(1).

(2) All Other Transfers and Exchanges of Beneficial Interests in Global Notes. In connection with all transfers and exchanges of beneficial interests that are not subject to Section 2.06(b)(1), the transferor of such beneficial interest must deliver to the Registrar either:

(A) both:

(i) an order from a Participant or an Indirect Participant given to the Depositary in accordance with the Applicable Procedures directing the Depositary to credit or cause to be credited a beneficial interest in another Global Note in an amount equal to the beneficial interest to be transferred or exchanged; and

(ii) instructions given in accordance with the Applicable Procedures containing information regarding the Participant account to be credited with such increase; or

(B) both:

(i) an order from a Participant or an Indirect Participant given to the Depositary in accordance with the Applicable Procedures directing the Depositary to cause to be issued a Definitive Note in an amount equal to the beneficial interest to be transferred or exchanged; and

(ii) instructions given by the Depositary to the Registrar containing information regarding the Person in whose name such Definitive Note shall be registered to effect the transfer or exchange referred to in (1) above;

 

58


provided that in no event shall Definitive Notes be issued upon the transfer or exchange of beneficial interests in the Regulation S Temporary Global Note prior to (A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903 under the Securities Act.

Upon satisfaction of all of the requirements for transfer or exchange of beneficial interests in Global Notes contained in this Indenture and the Notes or otherwise applicable under the Securities Act, the Trustee shall adjust the principal amount of the relevant Global Note(s) pursuant to Section 2.06(h).

(3) Transfer of Beneficial Interests to Another Restricted Global Note. A beneficial interest in any Restricted Global Note may be transferred to a Person who takes delivery thereof in the form of a beneficial interest in another Restricted Global Note if the transfer complies with the requirements of Section 2.06(b)(2) and the Registrar receives the following:

(A) if the transferee will take delivery in the form of a beneficial interest in the Rule 144A Global Note, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (1) thereof;

(B) if the transferee will take delivery in the form of a beneficial interest in the Regulation S Temporary Global Note or the Regulation S Permanent Global Note, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (2) thereof; and

(C) if the transferee will take delivery in the form of a beneficial interest in the IAI Global Note, then the transferor must deliver a certificate in the form of Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable.

(4) Transfer and Exchange of Beneficial Interests in a Restricted Global Note for Beneficial Interests in an Unrestricted Global Note. A beneficial interest in any Restricted Global Note may be exchanged by any Holder thereof for a beneficial interest in an Unrestricted Global Note or transferred to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note if the exchange or transfer complies with the requirements of Section 2.06(b)(2) and the Registrar receives the following:

(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a beneficial interest in an Unrestricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(a) thereof; or

(B) if the Holder of such beneficial interest in a Restricted Global Note proposes to transfer such beneficial interest to a Person who shall take delivery thereof in the form of a beneficial interest in an Unrestricted Global Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof; and, in each such case set forth in this clause (4), if the Registrar

 

59


so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Issuer to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

If any such transfer is effected pursuant to this clause (4) at a time when an Unrestricted Global Note has not yet been issued, the Issuer shall issue and, upon receipt of an Authentication Order in accordance with Section 2.02, the Trustee shall authenticate one or more Unrestricted Global Notes in an aggregate principal amount equal to the aggregate principal amount of beneficial interests transferred pursuant to this clause (4).

Beneficial interests in an Unrestricted Global Note cannot be exchanged for, or transferred to Persons who take delivery thereof in the form of, a beneficial interest in a Restricted Global Note.

(c) Transfer or Exchange of Beneficial Interests for Definitive Notes.

(1) Beneficial Interests in Restricted Global Notes to Restricted Definitive Notes. If any Holder of a beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a Restricted Definitive Note or to transfer such beneficial interest to a Person who takes delivery thereof in the form of a Restricted Definitive Note, then, upon receipt by the Registrar of the following documentation:

(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a Restricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (2)(a) thereof;

(B) if such beneficial interest is being transferred to a QIB in accordance with Rule 144A, a certificate to the effect set forth in Exhibit B, including the certifications in item (1) thereof;

(C) if such beneficial interest is being transferred to a Non-U.S. Person in an offshore transaction in accordance with Rule 903 or Rule 904, a certificate to the effect set forth in Exhibit B, including the certifications in item (2) thereof;

(D) if such beneficial interest is being transferred pursuant to an exemption from the registration requirements of the Securities Act in accordance with Rule 144, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(a) thereof;

(E) if such beneficial interest is being transferred to an Institutional Accredited Investor in reliance on an exemption from the registration requirements of the Securities Act other than those listed in subparagraphs (B) through (D) above, a certificate to the effect set forth in Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable;

 

60


(F) if such beneficial interest is being transferred to the Issuer or any of its Subsidiaries, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(b) thereof; or

(G) if such beneficial interest is being transferred pursuant to an effective registration statement under the Securities Act, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(c) thereof,

the Trustee shall cause the aggregate principal amount of the applicable Global Note to be reduced accordingly pursuant to Section 2.06(h), and the Issuer shall execute and the Trustee shall authenticate and deliver to the Person designated in the instructions a Definitive Note in the appropriate principal amount. Any Definitive Note issued in exchange for a beneficial interest in a Restricted Global Note pursuant to this Section 2.06(c) shall be registered in such name or names and in such authorized denomination or denominations as the Holder of such beneficial interest shall instruct the Registrar through instructions from the Depositary and the Participant or Indirect Participant. The Trustee shall deliver such Definitive Notes to Holders of such Notes. Any Definitive Note issued in exchange for a beneficial interest in a Restricted Global Note pursuant to this Section 2.06(c)(1) shall bear the Private Placement Legend and shall be subject to all restrictions on transfer contained therein.

(2) Beneficial Interests in Regulation S Temporary Global Note to Definitive Notes. Notwithstanding Sections 2.06(c)(1)(A) and (C), a beneficial interest in the Regulation S Temporary Global Note may not be exchanged for a Definitive Note or transferred to a Person who takes delivery thereof in the form of a Definitive Note prior to (A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903(b)(3)(ii)(B) under the Securities Act, except in the case of a transfer pursuant to an exemption from the registration requirements of the Securities Act other than Rule 903 or Rule 904.

(3) Beneficial Interests in Restricted Global Notes to Unrestricted Definitive Notes. A Holder of a beneficial interest in a Restricted Global Note may exchange such beneficial interest for an Unrestricted Definitive Note or may transfer such beneficial interest to a Person who takes delivery thereof in the form of an Unrestricted Definitive Note only if the Registrar receives the following:

(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(b) thereof; or

(B) if the Holder of such beneficial interest in a Restricted Global Note proposes to transfer such beneficial interest to a Person who shall take delivery thereof in the form of an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

 

61


and, in each such case set forth in this clause (3), if the Registrar so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Issuer to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

(4) Beneficial Interests in Unrestricted Global Notes to Unrestricted Definitive Notes. If any Holder of a beneficial interest in an Unrestricted Global Note proposes to exchange such beneficial interest for a Definitive Note or to transfer such beneficial interest to a Person who takes delivery thereof in the form of a Definitive Note, then, upon satisfaction of the conditions set forth in Section 2.06(b)(2), the Trustee will cause the aggregate principal amount of the applicable Global Note to be reduced accordingly pursuant to Section 2.06(h), and the Issuer will execute and the Trustee will authenticate and deliver to the Person designated in the instructions a Definitive Note in the appropriate principal amount. Any Definitive Note issued in exchange for a beneficial interest pursuant to this Section 2.06(c)(4) will be registered in such name or names and in such authorized denomination or denominations as the Holder of such beneficial interest requests through instructions to the Registrar from or through the Depositary and the Participant or Indirect Participant. The Trustee will deliver such Definitive Notes to Holders of such Notes. Any Definitive Note issued in exchange for a beneficial interest pursuant to this Section 2.06(c)(4) will not bear the Private Placement Legend.

(d) Transfer and Exchange of Definitive Notes for Beneficial Interests.

(1) Restricted Definitive Notes to Beneficial Interests in Restricted Global Notes. If any Holder of a Restricted Definitive Note proposes to exchange such Note for a beneficial interest in a Restricted Global Note or to transfer such Restricted Definitive Notes to a Person who takes delivery thereof in the form of a beneficial interest in a Restricted Global Note, then, upon receipt by the Registrar of the following documentation:

(A) if the Holder of such Restricted Definitive Note proposes to exchange such Note for a beneficial interest in a Restricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (2)(b) thereof;

(B) if such Restricted Definitive Note is being transferred to a QIB in accordance with Rule 144A, a certificate to the effect set forth in Exhibit B, including the certifications in item (1) thereof;

(C) if such Restricted Definitive Note is being transferred to a Non-U.S. Person in an offshore transaction in accordance with Rule 903 or Rule 904, a certificate to the effect set forth in Exhibit B, including the certifications in item (2) thereof;

(D) if such Restricted Definitive Note is being transferred pursuant to an exemption from the registration requirements of the Securities Act in accordance with Rule 144, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(a) thereof;

 

62


(E) if such Restricted Definitive Note is being transferred to an Institutional Accredited Investor in reliance on an exemption from the registration requirements of the Securities Act other than those listed in subparagraphs (B) through (D) above, a certificate to the effect set forth in Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable;

(F) if such Restricted Definitive Note is being transferred to the Issuer or any of its Subsidiaries, a certificate to the effect set forth in Exhibit B hereto, including the certifications in item (3)(b) thereof; or

(G) if such Restricted Definitive Note is being transferred pursuant to an effective registration statement under the Securities Act, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(c) thereof,

the Trustee will cancel the Restricted Definitive Note, increase or cause to be increased the aggregate principal amount of, in the case of clause (A) above, the appropriate Restricted Global Note, in the case of clause (B) above, the Rule 144A Global Note, in the case of clause (C) above, the Regulation S Global Note, in the case of clause (E) above, the IAI Global Note and in all other cases, the appropriate Unrestricted Global Note.

(2) Restricted Definitive Notes to Beneficial Interests in Unrestricted Global Notes. A Holder of a Restricted Definitive Note may exchange such Note for a beneficial interest in an Unrestricted Global Note or transfer such Restricted Definitive Note to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note only if the Registrar receives the following:

(A) if the Holder of such Definitive Notes proposes to exchange such Notes for a beneficial interest in the Unrestricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(c) thereof; or

(B) if the Holder of such Definitive Notes proposes to transfer such Notes to a Person who shall take delivery thereof in the form of a beneficial interest in the Unrestricted Global Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

and, in each such case set forth in this clause (2), if the Registrar so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Issuer to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

Upon satisfaction of the conditions of any of the subparagraphs in this Section 2.06(d)(2), the Trustee will cancel the Definitive Notes and increase or cause to be increased the aggregate principal amount of the Unrestricted Global Note.

 

63


(3) Unrestricted Definitive Notes to Beneficial Interests in Unrestricted Global Notes. A Holder of an Unrestricted Definitive Note may exchange such Note for a beneficial interest in an Unrestricted Global Note or transfer such Definitive Notes to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note at any time. Upon receipt of a request for such an exchange or transfer, the Trustee will cancel the applicable Unrestricted Definitive Note and increase or cause to be increased the aggregate principal amount of one of the Unrestricted Global Notes.

If any such exchange or transfer from a Definitive Note to a beneficial interest is effected pursuant to subparagraphs (2) or (3) above at a time when an Unrestricted Global Note has not yet been issued, the Issuer will issue and, upon receipt of an Authentication Order in accordance with Section 2.02, the Trustee will authenticate one or more Unrestricted Global Notes in an aggregate principal amount equal to the principal amount of Definitive Notes so transferred.

(e) Transfer and Exchange of Definitive Notes for Definitive Notes. Upon request by a Holder of Definitive Notes and such Holder’s compliance with the provisions of this Section 2.06(e), the Registrar will register the transfer or exchange of Definitive Notes. Prior to such registration of transfer or exchange, the requesting Holder must present or surrender to the Registrar the Definitive Notes duly endorsed or accompanied by a written instruction of transfer in form satisfactory to the Registrar duly executed by such Holder or by its attorney, duly authorized in writing. In addition, the requesting Holder must provide any additional certifications, documents and information, as applicable, required pursuant to the following provisions of this Section 2.06(e).

(1) Restricted Definitive Notes to Restricted Definitive Notes. Any Restricted Definitive Note may be transferred to and registered in the name of Persons who take delivery thereof in the form of a Restricted Definitive Note if the Registrar receives the following:

(A) if the transfer will be made pursuant to Rule 144A, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (1) thereof;

(B) if the transfer will be made pursuant to Rule 903 or Rule 904, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (2) thereof; and

(C) if the transfer will be made pursuant to any other exemption from the registration requirements of the Securities Act, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable.

(2) Restricted Definitive Notes to Unrestricted Definitive Notes. Any Restricted Definitive Note may be exchanged by the Holder thereof for an Unrestricted Definitive Note or transferred to a Person or Persons who take delivery thereof in the form of an Unrestricted Definitive Note if the Registrar receives the following:

(A) if the Holder of such Restricted Definitive Notes proposes to exchange such Notes for an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(d) thereof; or

 

64


(B) if the Holder of such Restricted Definitive Notes proposes to transfer such Notes to a Person who shall take delivery thereof in the form of an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

and, in each such case set forth in this clause (2), if the Registrar so requests, an Opinion of Counsel in form reasonably acceptable to the Registrar to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

(3) Unrestricted Definitive Notes to Unrestricted Definitive Notes. A Holder of Unrestricted Definitive Notes may transfer such Notes to a Person who takes delivery thereof in the form of an Unrestricted Definitive Note. Upon receipt of a request to register such a transfer, the Registrar shall register the Unrestricted Definitive Notes pursuant to the instructions from the Holder thereof.

(f) [Reserved].

(g) Legends. The following legends will appear on the face of all Global Notes and Definitive Notes issued under this Indenture unless specifically stated otherwise in the applicable provisions of this Indenture or any supplemental indenture governing Additional Notes.

(1) Private Placement Legend.

(A) Except as permitted by subparagraph (B) below, each Global Note and each Definitive Note (and all Notes issued in exchange therefor or substitution thereof) shall bear the legend in substantially the following form:

“THIS SECURITY HAS NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), OR THE SECURITIES LAWS OF ANY STATE OR OTHER JURISDICTION. NEITHER THIS SECURITY NOR ANY INTEREST OR PARTICIPATION HEREIN MAY BE REOFFERED, SOLD, ASSIGNED, TRANSFERRED, PLEDGED, ENCUMBERED OR OTHERWISE DISPOSED OF IN THE ABSENCE OF SUCH REGISTRATION OR UNLESS SUCH TRANSACTION IS EXEMPT FROM, OR NOT SUBJECT TO, SUCH REGISTRATION. THE HOLDER OF THIS SECURITY, BY ITS ACCEPTANCE HEREOF, AGREES ON ITS OWN BEHALF AND ON BEHALF OF ANY INVESTOR ACCOUNT FOR WHICH IT HAS PURCHASED SECURITIES, TO OFFER, SELL OR OTHERWISE TRANSFER SUCH SECURITY, ONLY (A) TO THE ISSUER, (B) PURSUANT TO A REGISTRATION STATEMENT THAT HAS BECOME OR BEEN DECLARED EFFECTIVE UNDER THE SECURITIES ACT, (C) FOR SO LONG

 

65


AS THE SECURITIES ARE ELIGIBLE FOR RESALE PURSUANT TO RULE 144A UNDER THE SECURITIES ACT, TO A PERSON IT REASONABLY BELIEVES IS A “QUALIFIED INSTITUTIONAL BUYER” AS DEFINED IN RULE 144A UNDER THE SECURITIES ACT THAT PURCHASES FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF A QUALIFIED INSTITUTIONAL BUYER TO WHOM NOTICE IS GIVEN THAT THE TRANSFER IS BEING MADE IN RELIANCE ON RULE 144A, (D) PURSUANT TO OFFERS AND SALES THAT OCCUR OUTSIDE THE UNITED STATES IN ACCORDANCE WITH REGULATION S UNDER THE SECURITIES ACT, (E) TO AN INSTITUTIONAL “ACCREDITED INVESTOR” WITHIN THE MEANING OF RULE 501(a)(1), (2), (3) OR (7) UNDER THE SECURITIES ACT THAT IS AN INSTITUTIONAL ACCREDITED INVESTOR ACQUIRING THE SECURITY FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF SUCH AN INSTITUTIONAL ACCREDITED INVESTOR, IN EACH CASE IN A MINIMUM PRINCIPAL AMOUNT OF THE SECURITIES OF $250,000, FOR INVESTMENT PURPOSES AND NOT WITH A VIEW TO OR FOR OFFER OR SALE IN CONNECTION WITH ANY DISTRIBUTION IN VIOLATION OF THE SECURITIES ACT, (F) PURSUANT TO THE EXEMPTION FROM REGISTRATION PROVIDED BY RULE 144 UNDER THE SECURITIES ACT (IF AVAILABLE) OR (G) PURSUANT TO ANOTHER AVAILABLE EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT, SUBJECT TO THE ISSUER’S AND THE TRUSTEE’S RIGHT PRIOR TO ANY SUCH OFFER, SALE OR TRANSFER PURSUANT TO CLAUSES (D), (E), (F) OR (G) TO REQUIRE THE DELIVERY OF AN OPINION OF COUNSEL, CERTIFICATION AND/OR OTHER INFORMATION SATISFACTORY TO EACH OF THEM. THIS LEGEND WILL BE REMOVED UPON THE REQUEST OF THE HOLDER AFTER THE RESALE RESTRICTION TERMINATION DATE.”

(B) Notwithstanding the foregoing, any Global Note or Definitive Note issued pursuant to subparagraphs (b)(4), (c)(3), (c)(4), (d)(2), (d)(3), (e)(2) or (e)(3) of this Section 2.06 (and all Notes issued in exchange therefor or substitution thereof) will not bear the Private Placement Legend.

(2) Global Note Legend. Each Global Note will bear a legend in substantially the following form:

“THIS GLOBAL NOTE IS HELD BY THE DEPOSITARY (AS DEFINED IN THE INDENTURE GOVERNING THIS NOTE) OR ITS NOMINEE IN CUSTODY FOR THE BENEFIT OF THE BENEFICIAL OWNERS HEREOF, AND IS NOT TRANSFERABLE TO ANY PERSON UNDER ANY CIRCUMSTANCES EXCEPT THAT (1) THE TRUSTEE MAY MAKE SUCH NOTATIONS HEREON AS MAY BE REQUIRED PURSUANT TO SECTION 2.06 OF THE INDENTURE, (2) THIS GLOBAL NOTE MAY BE EXCHANGED IN WHOLE BUT NOT IN PART PURSUANT TO SECTION 2.06(a) OF THE INDENTURE, (3) THIS GLOBAL NOTE MAY BE DELIVERED TO THE TRUSTEE FOR CANCELLATION PURSUANT TO SECTION 2.11 OF THE INDENTURE AND (4) THIS GLOBAL NOTE MAY BE TRANSFERRED TO A SUCCESSOR DEPOSITARY WITH THE PRIOR WRITTEN CONSENT OF THE ISSUER.

 

66


UNLESS AND UNTIL IT IS EXCHANGED IN WHOLE OR IN PART FOR NOTES IN DEFINITIVE FORM, THIS NOTE MAY NOT BE TRANSFERRED EXCEPT AS A WHOLE BY THE DEPOSITARY TO A NOMINEE OF THE DEPOSITARY OR BY A NOMINEE OF THE DEPOSITARY TO THE DEPOSITARY OR ANOTHER NOMINEE OF THE DEPOSITARY OR BY THE DEPOSITARY OR ANY SUCH NOMINEE TO A SUCCESSOR DEPOSITARY OR A NOMINEE OF SUCH SUCCESSOR DEPOSITARY. UNLESS THIS CERTIFICATE IS PRESENTED BY AN AUTHORIZED REPRESENTATIVE OF THE DEPOSITORY TRUST COMPANY (55 WATER STREET, NEW YORK, NEW YORK) (“DTC”), TO THE ISSUER OR ITS AGENT FOR REGISTRATION OF TRANSFER, EXCHANGE OR PAYMENT, AND ANY CERTIFICATE ISSUED IS REGISTERED IN THE NAME OF CEDE & CO. OR SUCH OTHER NAME AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC (AND ANY PAYMENT IS MADE TO CEDE & CO. OR SUCH OTHER ENTITY AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC), ANY TRANSFER, PLEDGE OR OTHER USE HEREOF FOR VALUE OR OTHERWISE BY OR TO ANY PERSON IS WRONGFUL INASMUCH AS THE REGISTERED OWNER HEREOF, CEDE & CO., HAS AN INTEREST HEREIN.”

(3) Regulation S Temporary Global Note Legend. The Regulation S Temporary Global Note will bear a legend in substantially the following form:

“THIS SECURITY HAS NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), OR THE SECURITIES LAWS OF ANY STATE OR OTHER JURISDICTION, AND MAY NOT BE OFFERED, SOLD OR DELIVERED IN THE UNITED STATES OR TO, OR FOR THE ACCOUNT OR BENEFIT OF, ANY US PERSON, UNLESS SUCH NOTES ARE REGISTERED UNDER THE SECURITIES ACT OR AN EXEMPTION FROM THE REGISTRATION REQUIREMENTS THEREOF IS AVAILABLE. THIS LEGEND WILL BE REMOVED AFTER THE EXPIRATION OF FORTY DAYS FROM THE LATER OF (i) THE DATE ON WHICH THESE NOTES WAS FIRST OFFERED AND (ii) THE DATE OF ISSUE OF THESE NOTES.”

(h) Cancellation and/or Adjustment of Global Notes. At such time as all beneficial interests in a particular Global Note have been exchanged for Definitive Notes or a particular Global Note has been redeemed, repurchased or canceled in whole and not in part, each such Global Note will be returned to or retained and canceled by the Trustee in accordance with Section 2.11. At any time prior to such cancellation, if any beneficial interest in a Global Note is exchanged for or transferred to a Person who will take delivery thereof in the form of a beneficial interest in another Global Note or for Definitive Notes, the principal amount of Notes represented by such Global Note will be reduced accordingly and an endorsement will be made on such Global

 

67


Note by the Trustee or by the Depositary at the direction of the Trustee to reflect such reduction; and if the beneficial interest is being exchanged for or transferred to a Person who will take delivery thereof in the form of a beneficial interest in another Global Note, such other Global Note will be increased accordingly and an endorsement will be made on such Global Note by the Trustee or by the Depositary at the direction of the Trustee to reflect such increase.

(i) General Provisions Relating to Transfers and Exchanges.

(1) To permit registrations of transfers and exchanges, the Issuer will execute and the Trustee will authenticate Global Notes and Definitive Notes upon receipt of an Authentication Order in accordance with Section 2.02 or at the Registrar’s request.

(2) No service charge will be made to a Holder of a beneficial interest in a Global Note or to a Holder of a Definitive Note for any registration of transfer or exchange, but the Issuer may require payment of a sum sufficient to cover any transfer tax or similar governmental charge payable in connection therewith (other than any such transfer taxes or similar governmental charge payable upon exchange or transfer pursuant to Section 2.10, Section 3.06, Section 3.09, Section 4.12 and Section 4.17).

(3) The Registrar will not be required to register the transfer of or exchange of any Note selected for redemption in whole or in part, except the unredeemed portion of any Note being redeemed in part.

(4) All Global Notes and Definitive Notes issued upon any registration of transfer or exchange of Global Notes or Definitive Notes will be the valid obligations of the Issuer, evidencing the same debt, and entitled to the same benefits under this Indenture, as the Global Notes or Definitive Notes surrendered upon such registration of transfer or exchange.

(5) Neither the Registrar nor the Issuer will be required:

(A) to issue, to register the transfer of or to exchange any Notes during a period beginning at the opening of business 15 days before the day of any selection of Notes for redemption under Section 3.02 and ending at the close of business on the day of selection;

(B) to register the transfer of or to exchange any Note selected for redemption in whole or in part, except the unredeemed portion of any Note being redeemed in part; or

(C) to register the transfer of or to exchange a Note between a record date and the next succeeding Interest Payment Date.

(6) Prior to due presentment for the registration of a transfer of any Note, the Trustee, any Agent and the Issuer may deem and treat any Holder as the absolute owner of such Note for the purpose of receiving payment of principal of and interest on such Notes and for all other purposes, and none of the Trustee, any Agent or the Issuer shall be affected by notice to the contrary.

 

68


(7) The Trustee will authenticate Global Notes and Definitive Notes in accordance with the provisions of Section 2.02.

(8) All certifications, certificates and Opinions of Counsel required to be submitted to the Registrar pursuant to this Section 2.06 to effect a registration of transfer or exchange may be submitted by facsimile.

(9) None of the Trustee or any Agent shall have any responsibility or obligation to any beneficial owner in a Global Note, an agent member of the Depositary or other Person with respect to the accuracy of the records of the Depositary or its nominee or of any agent member of the Depositary, with respect to any ownership interest in the Notes or with respect to the delivery to any agent member of the Depositary, beneficial owner or other Person (other than the Depositary) of any notice (including any notice of redemption) or the payment of any amount, under or with respect to such Notes. All notices and communications to be given to the Holders and all payments to be made to Holders under the Notes and this Indenture shall be given or made only to or upon the order of the registered holders (which shall be the Depositary or its nominee in the case of the Global Note). The rights of beneficial owners in the Global Note shall be exercised only through the Depositary subject to the applicable procedures. The Trustee and each Agent shall be entitled to rely and shall be fully protected in relying upon information furnished by the Depositary with respect to its members, participants and any beneficial owners. The Trustee and each Agent shall be entitled to deal with the Depositary, and any nominee thereof, that is the registered holder of any Global Note for all purposes of this Indenture relating to such Global Note (including the payment of principal, premium, if any, and interest, and the giving of instructions or directions by or to the owner or holder of a beneficial ownership interest in such Global Note) as the sole holder of such Global Note and shall have no obligations to the beneficial owners thereof. None of the Trustee or any Agent shall have any responsibility or liability for any acts or omissions of the Depositary with respect to such Global Note, for the records of any such depositary, including records in respect of beneficial ownership interests in respect of any such Global Note, for any transactions between the Depositary and any agent member of the Depositary or between or among the Depositary, any such agent member of the Depositary and/or any holder or owner of a beneficial interest in such Global Note, or for any transfers of beneficial interests in any such Global Note.

(10) Notwithstanding the foregoing, with respect to any Global Note, nothing herein shall prevent the Issuer, the Trustee, any Agent, or any agent of the Issuer or the Trustee from giving effect to any written certification, proxy or other authorization furnished by any Depositary (or its nominee), as a Holder, with respect to such Global Note or shall impair, as between such Depositary and owners of beneficial interests in such Global Note, the operation of customary practices governing the exercise of the rights of such Depositary (or its nominee) as Holder of such Global Note.

None of the Trustee or any Agent shall have any obligation or duty to monitor, determine or inquire as to compliance with any restrictions on transfer imposed under this Indenture or under applicable law with respect to any transfer of any interest in any security (including any transfers between or among Depositary participants, members or beneficial owners in any Global Note) other than to require delivery of such certificates and other documentation or evidence as are expressly required by, and to do so if and when expressly required by, the terms of this Indenture, and to examine the same to determine substantial compliance as to form with the express requirements hereof.

 

69


Section 2.07 Replacement Notes.

If any mutilated Note is surrendered to the Trustee or the Issuer and the Trustee receives evidence to its satisfaction of the destruction, loss or theft of any Note, the Issuer will issue and the Trustee, upon receipt of an Authentication Order, will authenticate a replacement Note if the Trustee’s requirements are met. If required by the Trustee or the Issuer, an indemnity bond must be supplied by the Holder that is sufficient in the judgment of the Trustee and the Issuer to protect the Issuer, the Trustee, any Agent and any authenticating agent from any loss that any of them may suffer if a Note is replaced. The Issuer may charge for its expenses in replacing a Note.

Every replacement Note is an additional obligation of the Issuer and will be entitled to all of the benefits of this Indenture equally and proportionately with all other Notes duly issued hereunder.

Section 2.08 Outstanding Notes.

The Notes outstanding at any time are all the Notes authenticated by the Trustee except for those canceled by it, those delivered to it for cancellation, those reductions in the interest in a Global Note effected in accordance with the provisions hereof, and those described in this Section 2.08 as not outstanding. Except as set forth in Section 2.09, a Note does not cease to be outstanding because the Issuer or an Affiliate of the Issuer holds the Note; however, Notes held by the Issuer or an Affiliate of the Issuer shall not be deemed to be outstanding for purposes of Section 3.07.

If a Note is replaced pursuant to Section 2.07, it ceases to be outstanding unless the Trustee receives proof satisfactory to it that the replacement Note is held by a “protected purchaser” under the UCC.

If the principal amount of any Note is considered paid under Section 4.01, it ceases to be outstanding and interest on it ceases to accrue.

If the Paying Agent (other than the Issuer, a Subsidiary or an Affiliate of any thereof) holds, on a redemption date or maturity date, money sufficient to pay Notes payable on that date, then on and after that date such Notes will be deemed to be no longer outstanding and will cease to accrue interest.

Section 2.09 Treasury Notes.

In determining whether the Holders of the required principal amount of Notes have concurred in any direction, waiver or consent, Notes owned by the Issuer or any Guarantor, or by any Person directly or indirectly controlling or controlled by or under direct or indirect common control with the Issuer or any Guarantor, will be considered as though not outstanding, except that for the purposes of determining whether the Trustee will be protected in relying on any such direction, waiver or consent, only Notes that the Trustee knows are so owned will be so disregarded.

 

70


Section 2.10 Temporary Notes.

Until certificates representing Notes are ready for delivery, the Issuer may prepare and the Trustee, upon receipt of an Authentication Order, will authenticate temporary Notes. Temporary Notes will be substantially in the form of certificated Notes but may have variations that the Issuer considers appropriate for temporary Notes and as may be reasonably acceptable to the Trustee. Without unreasonable delay, the Issuer will prepare and the Trustee will authenticate definitive Notes in exchange for temporary Notes.

Holders of temporary Notes will be entitled to all of the benefits of this Indenture.

Section 2.11 Cancellation.

The Issuer at any time may deliver Notes to the Trustee for cancellation. The Registrar and Paying Agent will forward to the Trustee any Notes surrendered to them for registration of transfer, exchange or payment. The Trustee and no one else will cancel all Notes surrendered for registration of transfer, exchange, payment, replacement or cancellation and will destroy canceled Notes (subject to the record retention requirement of the Exchange Act). Certification of the destruction of all canceled Notes will be delivered to the Issuer. The Issuer may not issue new Notes to replace Notes that it has paid or that have been delivered to the Trustee for cancellation.

Section 2.12 Defaulted Interest.

If the Issuer defaults in a payment of interest on the Notes, it will pay the defaulted interest in any lawful manner plus, to the extent lawful, interest payable on the defaulted interest, to the Persons who are Holders on a subsequent special record date, in each case at the rate provided in the Notes and in Section 4.01. The Issuer will notify the Trustee in writing of the amount of defaulted interest proposed to be paid on each Note and the date of the proposed payment. The Issuer will fix or cause to be fixed each such special record date and payment date; provided that no such special record date may be less than 10 days prior to the related payment date for such defaulted interest. At least 15 days before the special record date, the Issuer (or, upon the written request of the Issuer, the Trustee in the name and at the expense of the Issuer) will deliver Holders a notice that states the special record date, the related payment date and the amount of such interest to be paid.

ARTICLE 3

REDEMPTION AND PREPAYMENT

Section 3.01 Notices to Trustee.

If the Issuer elects to redeem Notes pursuant to the optional redemption provisions of Section 3.07, it must furnish to the Trustee, at least 10 days but not more than 60 days before a redemption date, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes of a series or a satisfaction and discharge of this Indenture pursuant to Article 8 or 12, an Officer’s Certificate setting forth:

(a) the Section of this Indenture pursuant to which the redemption shall occur;

 

71


(b) the redemption date;

(c) the series, or more than one series, if applicable, of Notes to be redeemed;

(d) the principal amount of Notes to be redeemed;

(e) the redemption price; and

(f) the CUSIP number of the Notes to be redeemed.

Section 3.02 Selection of Notes to Be Redeemed.

If less than all of the Notes are to be redeemed at any time, or less than all of the Notes of a particular series are to be redeemed, the Trustee will select Notes for redemption by lot, on a pro rata basis (provided that, in the case of Global Notes, Global Notes shall be selected for redemption pursuant to the Applicable Procedures) and, if applicable, with such adjustments so that only Notes in denominations of $2,000 or whole multiples of $1,000 in excess thereof will be purchased unless otherwise required by law, Applicable Procedures, or applicable stock exchange requirements; provided that if only Notes of a particular series are to be redeemed, such selection shall be limited to Notes of such series.

No Notes of $2,000 or less can be redeemed in part. In the event of partial redemption, the particular Notes to be redeemed will be selected, unless otherwise provided herein, not less than 10 nor more than 60 days prior to the redemption or purchase date by the Trustee from the outstanding Notes not previously called for redemption.

The Trustee will promptly notify the Issuer in writing of the Notes selected for redemption and, in the case of any Note selected for partial redemption, the principal amount thereof to be redeemed. Notes and portions of Notes selected will be in amounts of $2,000 or whole multiples of $1,000 in excess thereof; except that if all of the Notes of a Holder are to be redeemed, the entire outstanding amount of Notes held by such Holder, even if not in the amount of $2,000 or a whole multiple of $1,000 thereof, shall be redeemed. Except as provided in the preceding sentence, provisions of this Indenture that apply to Notes called for redemption also apply to portions of Notes called for redemption.

Section 3.03 Notice of Redemption.

At least 10 days but not more than 60 days before a redemption date, the Issuer will deliver a notice of redemption to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes of a series or a satisfaction and discharge of this Indenture pursuant to Article 8 or 12.

 

72


The notice will identify the Notes to be redeemed and will state:

(a) the redemption date;

(b) the redemption price, or if not then ascertainable, the manner of calculation thereof;

(c) if any Note is being redeemed in part, the portion of the principal amount of such Note to be redeemed and that, after the redemption date upon surrender of such Note, a new Note or Notes in principal amount equal to the unredeemed portion will be issued in the name of the Holder upon cancellation of the original Note;

(d) the name and address of the Paying Agent;

(e) that Notes called for redemption must be surrendered to the Paying Agent to collect the redemption price;

(f) that, unless the Issuer defaults in making such redemption payment, interest on Notes called for redemption ceases to accrue on and after the redemption date;

(g) the paragraph of the Notes and/or Section of this Indenture pursuant to which the Notes called for redemption are being redeemed;

(h) that no representation is made as to the correctness or accuracy of the CUSIP number, if any, listed in such notice or printed on the Notes; and

(i) any conditions precedent to which the redemption is subject.

At the Issuer’s request, the Trustee will give the notice of redemption in the Issuer’s name and at its expense; provided, however, that the Issuer has delivered to the Trustee, at least 10 days prior to the redemption date (unless a shorter period is acceptable to the Trustee), an Officer’s Certificate requesting that the Trustee give such notice and setting forth the form of notice to be provided.

Any such redemption may, at the Issuer’s discretion, be subject to one or more conditions precedent, including completion of any related Equity Offerings, Change of Control or other transaction. If such redemption is subject to the satisfaction of one or more conditions precedent, the related notice of redemption shall describe each such condition, and if applicable, shall state that, in the Issuer’s discretion, the redemption date may be delayed until such time as any or all such conditions shall be satisfied or waived, or such redemption may not occur and such notice may be rescinded in the event that any or all such conditions shall not have been satisfied or waived by the redemption date, or by the redemption date as so delayed. In addition, the Issuer may provide in such notice that payment of the redemption price and performance of the Issuer’s obligations with respect to such redemption may be performed by another Person (it being understood that any such provision for payment by another Person will not relieve the Issuer and the Guarantors from their obligations with respect to such redemption in the event such other person fails to do so and all conditions to such redemption, if any, are satisfied).

 

73


Section 3.04 Effect of Notice of Redemption.

Once notice of redemption is delivered in accordance with Section 3.03, Notes called for redemption become irrevocably due and payable on the redemption date at the redemption price, subject to the fourth paragraph of Section 3.03.

Section 3.05 Deposit of Redemption Price.

Prior to 11:00 a.m. (New York City time) on the redemption date, the Issuer shall deposit with the Paying Agent money sufficient to pay the redemption price of and accrued and unpaid interest on all Notes to be redeemed on that redemption date; provided, however, that to the extent any such funds are received by the Paying Agent from the Issuer after such time on such due date, such funds will be distributed to such Persons as promptly as practicable. The Paying Agent shall promptly return to the Issuer any money deposited with such Paying Agent by the Issuer in excess of the amounts necessary to pay the redemption price of, and accrued and unpaid interest on, all Notes to be redeemed.

If the Issuer complies with the provisions of the preceding paragraph, on and after the redemption date, interest will cease to accrue on the Notes or the portions of Notes called for redemption. If a Note is redeemed on or after an interest record date but on or prior to the related Interest Payment Date, then any accrued and unpaid interest shall be paid to the Holder as at the close of business on such record date. If any Note called for redemption is not so paid upon surrender for redemption because of the failure of the Issuer to comply with the preceding paragraph, interest shall be paid on the unpaid principal, from the redemption or purchase date until such principal is paid, and to the extent lawful on any interest not paid on such unpaid principal, in each case at the rate provided in the Notes and in Section 4.01.

Section 3.06 Notes Redeemed or Purchased in Part.

Upon surrender of a Note that is redeemed in part, the Issuer will issue and, upon receipt of an Authentication Order, the Trustee will authenticate for the Holder at the expense of the Issuer a new Note equal in principal amount to the unredeemed portion of the Note surrendered.

Section 3.07 Optional Redemption.

(a) At any time prior to June 1, 2025 (in respect of the 2028 Notes) and June 1, 2026 (in respect of the 2031 Notes), the Issuer may on any one or more occasions redeem up to 40% of the aggregate principal amount of all Notes of a series issued under this Indenture prior to the redemption date, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to (i) in respect of the 2028 Notes, 108.125% of the principal amount of the 2028 Notes redeemed, and (ii) in respect of the 2031 Notes, 108.375% of the principal amount of the 2031 Notes redeemed, in each case, plus accrued and unpaid interest, if any, to the redemption date with an amount not to exceed the amount of net cash proceeds of one or more Equity Offerings consummated after the Issue Date; provided that:

(1) at least 50% of the aggregate principal amount of Notes of such series issued under this Indenture on the Issue Date (excluding Notes held by the Issuer and its Subsidiaries) remains outstanding immediately after the occurrence of such redemption (unless all such Notes are otherwise repurchased or redeemed pursuant to another provision described under this Article 3); and

 

74


(2) the redemption occurs within 180 days of the date of the closing of such Equity Offering.

(b) At any time prior to June 1, 2025 (in respect of the 2028 Notes) and June 1, 2026 (in respect of the 2031 Notes), the Issuer may on any one or more occasions redeem all or any part of the Notes of a series upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 100% of the principal amount of the Notes redeemed, plus the Applicable Redemption Premium as of, and accrued and unpaid interest, if any, to the date of redemption.

(c) On or after June 1, 2025 (in respect of the 2028 Notes) and June 1, 2026 (in respect of the 2031 Notes), the Issuer may on any one or more occasions redeem all or any part of the Notes of a series, upon not less than 10 nor more than 60 days’ notice, at the redemption prices (expressed as a percentage of principal amount of the Notes of such series) set forth below, plus accrued and unpaid interest, if any, to the applicable redemption date, if redeemed during the twelve-month period beginning on June 1 of the years indicated below:

2028 Notes

 

Year

  

Percentage

2025

   104.063%

2026

   102.031%

2027 and thereafter

   100.000%

2031 Notes

 

Year

  

Percentage

2026

   104.188%

2027

   102.094%

2028 and thereafter

   100.000%

Unless the Issuer defaults in the payment of the redemption price, interest will cease to accrue on the Notes of any series or portions thereof called for redemption on the applicable redemption date.

(d) Any redemption pursuant to this Section 3.07 shall be made pursuant to the provisions of Sections 3.01 through 3.06 hereof.

(e) Notwithstanding the foregoing, in connection with any tender offer for any series of Notes, including a Change of Control Offer or Asset Sale Offer for the Notes, if Holders of not less than 90% in aggregate principal amount of the then outstanding Notes of any series validly tender and do not validly withdraw such Notes in such offer and the Issuer, or any third party making such offer in lieu of the Issuer, purchase all of the Notes of such series validly tendered and not validly withdrawn by such Holders, all of the Holders of the Notes of such series will be deemed to have consented to such tender or other offer, and accordingly the Issuer or such third party will have the right upon not less than 10 nor more than 60 days’ prior notice, given not more

 

75


than 15 days following such purchase date, to redeem all Notes of such series that remain outstanding following such purchase at a price equal to the price offered to each other Holder in such offer (which may be less than par) plus, to the extent not included in the offer payment, accrued and unpaid interest, if any, thereon, to, but excluding, the redemption date, subject to the right of Holders of record on the relevant record date to receive interest due on the relevant Interest Payment Date falling prior to or on the redemption date. In determining whether the Holders of at least 90% of the aggregate principal amount of the then outstanding Notes of a series have validly tendered and not validly withdrawn Notes in a tender offer for any series of Notes, including a Change of Control Offer or Asset Sale Offer, as applicable, Notes owned by an Affiliate of the Issuer or by funds controlled or managed by any Affiliate of the Issuer, or any successor thereof, shall be deemed to be outstanding for the purposes of such tender offer for any series of Notes, including a Change of Control Offer or Asset Sale Offer, as applicable.

Section 3.08 Mandatory Redemption; Purchases of Notes.

The Issuer will not be required to make any mandatory redemption or sinking fund payments with respect to the Notes. The Issuer, the Restricted Subsidiaries and their respective Affiliates may at any time and from time to time purchase the Notes in the open market, by tender offer, in negotiated transactions or otherwise.

Section 3.09 Offer to Purchase by Application of Excess Proceeds.

(a) In the event that, pursuant to Section 4.10 hereof, the Issuer shall be required to commence a Collateral Asset Sale Offer or an Asset Sale Offer, or if the Issuer shall elect to commence a Collateral Advance Offer or Advance Offer, the Issuer shall follow the procedures specified below.

(b) The Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall remain open for a period of 20 Business Days following its commencement and no longer, except to the extent that a longer period is required by applicable law (the “Offer Period”). No later than five Business Days after the termination of the Offer Period (the “Purchase Date”), the Issuer shall apply all Collateral Excess Proceeds or Excess Proceeds, as the case may be (the “Offer Amount”), to the purchase of Notes and, if required or permitted by the terms thereof, to other First Lien Obligations (in the case of Collateral Excess Proceeds) or to any other Senior Indebtedness (in the case of Excess Proceeds) (on a pro rata basis, if applicable, with adjustments as necessary so that no Notes or other First Lien Obligations or Senior Indebtedness, as the case may be, will be repurchased in part in an unauthorized denomination), or, if less than the Offer Amount has been tendered, all Notes and other First Lien Obligations (in the case of Collateral Excess Proceeds), or all Notes and any other Senior Indebtedness (in the case of Excess Proceeds), in each case, tendered in response to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be. Payment for any Notes so purchased shall be made in the same manner as interest payments are made.

(c) If the Purchase Date is on or after a record date and on or before the related Interest Payment Date, any accrued and unpaid interest, if any, up to but excluding the Purchase Date shall be paid to the Holder at the close of business on such record date, and no additional interest shall be payable to Holders who tender Notes pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be.

 

76


(d) Upon the commencement of a Collateral Asset Sale Offer, a Collateral Advance Offer, an Asset Sale Offer or an Advance Offer, as the case may be, the Issuer shall send, electronically or by first-class mail, a notice to each of the Holders, with a copy to the Trustee. The notice shall contain all instructions and materials necessary to enable such Holders to tender Notes pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be. The Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall be made to all Holders and, if required or permitted by the terms thereof, holders of other First Lien Obligations (in the case of Collateral Excess Proceeds) or any other Senior Indebtedness (in the case of Excess Proceeds). The notice, which shall govern the terms of the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall state:

(1) that the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, is being made pursuant to this Section 3.08 and Section 4.10 hereof and the length of time the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall remain open;

(2) the Offer Amount, the purchase price and the Purchase Date;

(3) that any Note not tendered or accepted for payment shall continue to accrue interest;

(4) that, unless the Issuer defaults in making such payment, any Note accepted for payment pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall cease to accrue interest on and after the Purchase Date;

(5) that any Holder electing to have less than all of the aggregate principal amount of its Notes purchased pursuant to a Collateral Asset Sale Offer, a Collateral Advance Offer, an Asset Sale Offer or an Advance Offer, as the case may be, may elect to have Notes purchased in integral multiples of $1,000;

(6) that Holders electing to have a Note purchased pursuant to any Collateral Asset Sale Offer, Collateral Advance Offer, Asset Sale Offer or Advance Offer, as the case may be, shall be required to surrender the Note, with the form entitled “Option of Holder to Elect Purchase” attached to the Note completed, or transfer such Note by book-entry transfer, to the Issuer, the applicable Depositary, if appointed by the Issuer, or a Paying Agent at the address specified in the notice at least two Business Days before the Purchase Date;

(7) that Holders shall be entitled to withdraw their election if the Issuer, the applicable Depositary or the Paying Agent, as the case may be, receives, not later than the close of business on the tenth Business Day prior to the expiration date of the Offer Period, a facsimile transmission or letter setting forth the name of the Holder, the principal amount of the Note the Holder delivered for purchase and a statement that such Holder is withdrawing his election to have such Note purchased;

 

77


(8) that, if the aggregate principal amount of Notes and, if applicable, other First Lien Obligations (in the case of Collateral Excess Proceeds) or any other senior Indebtedness (in the case of Excess Proceeds), in each case, surrendered by the holders thereof exceeds the Offer Amount (or, in the case of an Collateral Advance Offer or an Advance Offer, the Collateral Advance Portion or Advance Portion, respectively), the Issuer shall purchase such Notes (subject to Applicable Procedures as to Global Notes) and such other First Lien Obligations or Senior Indebtedness, as the case may be, on a pro rata basis based on the aggregate principal amount (or accreted value, if applicable) of the Notes or such other First Lien Obligations or Senior Indebtedness, as the case may be, tendered (with such adjustments as may be deemed appropriate by the Issuer so that only Notes in integral multiples of $1,000 are purchased); and

(9) that Holders whose certificated Notes were purchased only in part shall be issued new Notes equal in principal amount to the unpurchased portion of the Notes surrendered (or transferred by book-entry transfer) representing the same Indebtedness to the extent not repurchased; provided that new Notes will only be issued in denominations of $2,000 and in integral multiples of $1,000 in excess thereof.

The notice, if delivered electronically or mailed in a manner herein provided, shall be conclusively presumed to have been given, whether or not the Holder receives such notice. If (i) the notice is delivered or mailed in a manner herein provided and (ii) any Holder fails to receive such notice or a Holder receives such notice but it is defective, such Holder’s failure to receive such notice or such defect shall not affect the validity of the proceedings for the purchase of the Notes as to all other Holders that properly received such notice without defect.

(e) On or before the Purchase Date, the Issuer shall, to the extent lawful, (1) accept for payment, on a pro rata basis as described in clause (d)(8) of this Section 3.09, the Offer Amount of Notes or portions thereof validly tendered pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, or if less than the Offer Amount has been tendered, all Notes tendered and (2) deliver or cause to be delivered to the Trustee the Notes properly accepted, together with an Officer’s Certificate stating the aggregate principal amount of Notes or portions thereof so tendered.

(f) The Issuer, the Depositary or the Paying Agent, as the case may be, shall promptly deliver to each tendering Holder an amount equal to the purchase price of the Notes properly tendered by such Holder and accepted by the Issuer for purchase, and the Issuer shall promptly issue a new Note, and the Trustee, upon receipt of an Authentication Order, shall authenticate and mail or deliver (or cause to be transferred by book-entry) such new Note to such Holder (it being understood that, notwithstanding anything in this Indenture to the contrary, only an Officer’s Certificate and not an Opinion of Counsel is required for the Trustee to authenticate and deliver such new Note) in a principal amount equal to any unpurchased portion of the Note surrendered representing the same Indebtedness to the extent not repurchased; provided, that each such new Note shall be in a principal amount of $2,000 or an integral multiple of $1,000 in excess thereof.

 

78


Any Note not so accepted shall be promptly mailed or delivered by the Issuer to the Holder thereof. The Issuer shall announce the results of the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, on or as soon as practicable after the Purchase Date on the website or online data system maintain pursuant to Section 4.03(a) hereof.

(g) Prior to 11:00 a.m. (New York City time) on the Purchase Date, the Issuer shall deposit with the Paying Agent money sufficient to pay the purchase price of and accrued and unpaid interest on all Notes to be purchased on that Purchase Date; provided, however, that to the extent any such funds are received by the Paying Agent from the Issuer after such time on such due date, such funds will be distributed to such Persons as promptly as practicable. The Paying Agent shall promptly return to the Issuer any money deposited with the Paying Agent by the Issuer in excess of the amounts necessary to pay the purchase price of, and accrued and unpaid interest on, all Notes to be redeemed.

Other than as specifically provided in this Section 3.08 or Section 4.10 hereof, any purchase pursuant to this Section 3.08 shall be made pursuant to the applicable provisions of Sections 3.01 through 3.06 hereof, and references therein to “redeem,” “redemption,” “Redemption Date” and similar words shall be deemed to refer to “purchase,” “repurchase,” “Purchase Date” and similar words, as applicable.

ARTICLE 4

COVENANTS

Section 4.01 Payment of Notes.

The Issuer will pay or cause to be paid the principal of, premium, if any, and interest, if any, on, the Notes of each series on the dates and in the manner provided in the Notes of each series. Principal, premium, if any, and interest, if any, will be considered paid on the date due if the Paying Agent, if other than the Issuer or a Subsidiary thereof, holds as of 11:00 a.m. (New York City time) on the due date money deposited by the Issuer in immediately available funds and designated for and sufficient to pay all principal, premium, if any, and interest, if any, then due.

Section 4.02 Maintenance of Office or Agency.

The Issuer will maintain in the Borough of Manhattan, the City of New York, an office or agency (which may be an office of the Trustee or an Affiliate of the Trustee, Registrar or co- registrar) where Notes may be surrendered for registration of transfer or for exchange and where notices and demands to or upon the Issuer in respect of the Notes and this Indenture may be served. The Issuer will give prompt written notice to the Trustee of the location, and any change in the location, of such office or agency. If at any time the Issuer fails to maintain any such required office or agency or fails to furnish the Trustee with the address thereof, such presentations, surrenders, notices and demands may be made or served at the Corporate Trust Office of the Trustee.

 

79


The Issuer may also from time to time designate one or more other offices or agencies where the Notes may be presented or surrendered for any or all such purposes and may from time to time rescind such designations; provided, however, that no such designation or rescission will in any manner relieve the Issuer of its obligation to maintain an office or agency in the Borough of Manhattan, the City of New York for such purposes. The Issuer will give prompt written notice to the Trustee of any such designation or rescission and of any change in the location of any such other office or agency.

The Issuer hereby designates the Corporate Trust Office of the Trustee as one such office or agency of the Issuer in accordance with Section 2.03.

Section 4.03 Reports.

The Issuer will deliver to the Trustee and make available to the Holders of the Notes, without cost to the Trustee or any Holder:

(a) within 120 days after the end of each fiscal year of the Issuer, an annual report containing, to the extent applicable, the following information:

(1) audited consolidated balance sheets of the Issuer and audited consolidated income statements and audited statements of cash flow of the Issuer as of and for the two most recent fiscal years, including appropriate footnotes to such financial statements, audited by an internationally recognized firm of independent public accountants, and the report of the independent public accountants of the Issuer on such financial statements; and

(2) a “management’s discussion and analysis” of the results of operations of the Issuer and its Subsidiaries on a consolidated basis for the periods presented in a level of detail comparable to the management’s discussion and analysis of the results of operations contained in the Offering Memorandum;

(b) within 60 days after the end of the first three fiscal quarters in each fiscal year of the Issuer, a quarterly report containing, to the extent applicable, the following information:

(1) an unaudited condensed consolidated balance sheet of the Issuer as of the end of such fiscal quarter and unaudited condensed statements of income and cash flow for the most recent fiscal interim period ending on the date of the unaudited condensed balance sheet, and the comparable prior year period (or comparable prior year end, in the case of such balance sheet), together with condensed footnote disclosure; and

(2) a “management’s discussion and analysis” of the results of operations of the Issuer and its Subsidiaries on a consolidated basis for the periods presented in a level of detail comparable to the management’s discussion and analysis of the results of operations contained in the Offering Memorandum;

(c) within 10 Business Days after the occurrence of any event that would require a filing with the Commission on Form 8-K under Items 1.03, 2.01 (only with respect to acquisitions that the Issuer determines in good faith are material to holders of the Notes), 4.01, 4.02(a) and (b), 5.01 and 5.02(b) (with respect to the principal executive officer, president, principal financial officer, principal accounting officer and principal operating officer only) as in effect as of the Issue Date, a notice or report containing a brief description of such event.

 

80


All such annual and quarterly financial statements will be prepared in accordance with GAAP (with the absence of year-end adjustments in the case of quarterly financial statements). For the avoidance of doubt, no report needs to include separate financial statements for the Issuer, any Guarantor or any Subsidiary that is not a Guarantor.

Notwithstanding the foregoing, with respect to any financial statements, reports, information and other disclosures provided in clauses (a) through (c) above, such (A) such financial statements, reports, information and other disclosures shall not be required to include as an exhibit, or to include a summary of the terms of, any employment or compensatory arrangement, agreement, plan or understanding between the Issuer (or any Parent Entity or Subsidiaries of the Issuer) and any director, manager or officer, of the Issuer (or any Parent Entity or Subsidiaries of the Issuer), (B) the Issuer shall not be required to make available any information regarding the occurrence of any of the events set forth in clause (c) above if the Issuer determines in its good faith judgment that the event that would otherwise be required to be disclosed is not material to the holders of the Notes or the business, assets, operations, financial positions or prospects of the Issuer and its Restricted Subsidiaries taken as a whole, (C) no such financial statements, reports, information or other disclosures will be required to comply with Regulation G under the Exchange Act or Item 10(e) of Regulation S-K with respect to any “non-GAAP” financial information contained therein, (D) no such report will be required to comply with Regulation S-K or Regulation S-X including, without limitation, Rules 3-05, 3-09, 3-10, 3-16, 13-01, 13-02 or Article 11 thereof,

(E) no such financial statements, reports, information or other disclosures will be required to provide any information that is not otherwise similar to information currently included in the Offering Memorandum, (F) in no event will such financial statements, reports, information or other disclosures be required to include as an exhibit copies of any agreements, financial statements or other items that would be required to be filed as exhibits under the Commission rules, (G) trade secrets and other information that could, in the Issuer’s good faith judgment, cause competitive harm to the Issuer and its Subsidiaries may be excluded from any such financial statements, reports, information or other disclosures, (H) such financial statements or information will not be required to contain any “segment reporting,” (I) such financial statements and information may, at the election of the Issuer, be prepared in accordance with GAAP or IFRS, (J) the Issuer may elect to change its fiscal year end, and (K) no acquired business financial statements or pro forma financial statements shall be required to be disclosed.

If the Issuer or any Parent Entity does not file reports containing such information with the SEC, then the Issuer shall make available such financial statements, reports, information and other disclosures to any Holder, in each case by posting such information on a password-protected website or online data system which shall require a confidentiality acknowledgment, and will make such information readily available to any bona fide prospective investor who agrees to treat such information as confidential; provided that the Issuer shall post such financial statements, reports, information and other disclosures thereon and make readily available any password or other login information to any such bona fide prospective investor; provided, however, that the Issuer may deny access to any competitively-sensitive information otherwise to be provided pursuant to this Section 4.03 to any such Holder or bona fide prospective investor to the extent that the Issuer determines in good faith that the provision of such information to such Person would be competitively harmful to the Issuer and its Subsidiaries; and provided, further, that such Holders and bona fide prospective investors shall agree to (A) treat all such financial statements, reports, information and other disclosures as confidential, (B) not to use such financial statements, reports, information and other disclosures for any purpose other than their investment or potential investment in the Notes and (C) not publicly disclose any such financial statements, reports, information and other disclosures.

 

81


To the extent not satisfied by this Section 4.03, the Issuer shall furnish to holders of Notes and prospective investors, upon their request, any information required to be delivered pursuant to Rule 144A(d)(4) under the Securities Act so long as the Notes are not freely transferable under the Securities Act by persons who are not “affiliates” as defined under the Securities Act.

Notwithstanding the foregoing, the Issuer may satisfy its obligations in this Section 4.03 with respect to financial information relating to the Issuer by furnishing financial information relating to any Parent Entity; provided that, if such financial information relates to any such Parent Entity that is not a Guarantor, then the same is accompanied by selected financial metrics that show the differences (in the Issuer’s sole discretion) between the information relating to such Parent Entity, on the one hand, and the information relating to the Issuer and its Subsidiaries on a standalone basis, on the other hand.

The Issuer shall use its commercially reasonable efforts to participate in quarterly conference calls (which may be a single conference call together with investors and lenders holding other securities or Indebtedness of the Issuer, its Restricted Subsidiaries and/or any direct or indirect parent of the Issuer) to discuss results of operations. The conference call will be following the last day of each fiscal quarter of the Issuer within a reasonable period of time following the time that the Issuer distributes the financial information as set forth in clauses (a) and (b) above. Prior to the conference call, the Issuer will issue a press release or otherwise announce the time and date of such conference call and provide instructions for holders of Notes, prospective investors in the Notes, securities analysts and market making financial institutions to obtain access to such call.

To the extent any information is not provided within the time periods specified in this Section 4.03 and such information is subsequently provided, the Issuer will be deemed to have satisfied its obligations with respect thereto at such time and any Default with respect thereto shall be deemed to have been cured.

The Trustee shall not be obligated or under any duty to monitor or confirm, on a continuing basis or otherwise, the Issuer’s compliance with the covenants or with respect to any reports or other documents posted to Intralinks or another password protected website or data system or filed with the Commission or EDGAR or any website, or to participate in any conference calls.

The delivery of such reports, information and documents to the Trustee is for informational purposes only and the Trustee’s receipt of such shall not constitute actual or constructive notice of any information contained therein or determinable from information contained therein, including the Issuer’s compliance with any of its covenants in this Indenture (as to which the Trustee is entitled to rely exclusively on Officer’s Certificates).

 

82


Section 4.04 Compliance Certificate.

(a) The Issuer shall deliver to the Trustee, within 120 days after the end of each fiscal year of the Issuer and, if timely, accompanying the annual financial statements as described in Section 4.03 of this Indenture, a statement regarding compliance with this Indenture in an Officer’s Certificate also confirming that, to the signing officer’s knowledge, no Event of Default or Default has occurred and is continuing which has not been waived, or, if the same has occurred, a description of any measures taken or proposed to be taken by the Issuer to address the same.

(b) So long as any of the Notes are outstanding, the Issuer will deliver to the Trustee, within 20 Business Days of any of their Officers becoming aware of any Default or Event of Default, an Officer’s Certificate specifying such Default or Event of Default and what action the Issuer is taking or propose to take with respect thereto, but only to the extent such Default or Event of Default has not been cured by the end of such 20 Business Day period.

Section 4.05 Taxes.

Each of the Issuer and its respective Restricted Subsidiaries (or, for the purposes of this Section 4.05, if such entity is a disregarded entity for U.S. federal income tax purposes, its owner for U.S. federal income tax purposes) will pay or cause to be paid all material Taxes (if any) imposed on it or its property by any Governmental Authority, when due, giving effect to any applicable extensions, unless these are being contested in good faith and by appropriate proceedings and an appropriate reserve has been established in respect thereof in accordance with GAAP.

Section 4.06 Stay, Extension and Usury Laws.

The Issuer and each of the Guarantors covenants (to the extent that it may lawfully do so) that it will not at any time insist upon, plead, or in any manner whatsoever claim or take the benefit or advantage of, any stay, extension or usury law wherever enacted, now or at any time hereafter in force, that may affect the covenants or the performance of this Indenture; and the Issuer and each of the Guarantors (to the extent that it may lawfully do so) hereby expressly waives all benefit or advantage of any such law, and covenants that it will not, by resort to any such law, hinder, delay or impede the execution of any power herein granted to the Trustee, but will suffer and permit the execution of every such power as though no such law has been enacted.

Section 4.07 Limitation on Restricted Payments.

(a) The Issuer will not, and will not permit any of its Restricted Subsidiaries to, directly or indirectly:

(1) declare or pay any dividend or make any other payment or distribution on account of the Issuer’s or any of its Restricted Subsidiaries’ Equity Interests (including, without limitation, any payment in connection with any merger or consolidation involving the Issuer or its Restricted Subsidiaries) or to the direct or indirect holders of the Issuer’s or any of its Restricted Subsidiaries’ Equity Interests in their capacity as holders (other than dividends or distributions payable in Equity Interests (other than Disqualified Stock) of the Issuer or any of its Restricted Subsidiaries and other than dividends or distributions payable to the Issuer or its Restricted Subsidiaries on at least a pro rata basis);

(2) purchase, redeem or otherwise acquire or retire for value (including, without limitation, in connection with any merger or consolidation involving the Issuer) any Equity Interests of the Issuer or any Parent Entity other than Equity Interests held by the Issuer or any of its Restricted Subsidiaries;

 

83


(3) make any principal payment on, or purchase, repurchase, redeem, defease or otherwise acquire or retire for value, prior to scheduled maturity, scheduled repayment or scheduled sinking fund payment, any subordinated Indebtedness (excluding any intercompany Indebtedness between or among the Issuer and any of its Restricted Subsidiaries), except (i) a payment of principal at the Stated Maturity thereof or (ii) the purchase, repurchase, redemption, defeasance or other acquisition or retirement for value of any subordinated Indebtedness in anticipation of satisfying a sinking fund obligation, principal installment or payment at final maturity, in each case due within one year of the date of purchase, repurchase, redemption, defeasance or other acquisition or retirement for value; or

(4) make any Restricted Investment in any Person,

(all such payments and other actions set forth in clauses (1) through (4) above being collectively referred to as “Restricted Payments”), unless, at the time of any such Restricted Payment, no Event of Default has occurred and is continuing or would occur as a consequence of such Restricted Payment, and:

(A) if the Fixed Charge Coverage Ratio for the applicable Test Period at the time of such Restricted Payment is greater than or equal to 1.75 to 1.00, such Restricted Payment, together with the aggregate amount of all other Restricted Payments made by the Issuer and its Restricted Subsidiaries since the Issue Date (excluding Restricted Payments permitted by clauses (2) through (23) of Section 4.07(b)), is less than the sum, without duplication, of:

(i) Cumulative Distributable Cash, determined as of the date such Restricted Payment is made; plus

(ii) 100% of the aggregate net cash proceeds and the Fair Market Value of marketable securities and other property received by the Issuer since the Issue Date (x) as a contribution to its common equity capital or (y) in consideration of the sale or issuance of Equity Interests of the Issuer (other than Disqualified Stock or Designated Preferred Stock) or from the issue or sale of convertible or exchangeable Disqualified Stock of the Issuer or convertible or exchangeable Indebtedness of the Issuer, in each case that have been converted into or exchanged for Equity Interests of the Issuer or any Parent Entity (other than Equity Interests (or Disqualified Stock or convertible or exchangeable Indebtedness) sold to a Subsidiary of the Issuer); plus

(iii) the aggregate amount of Retained Asset Sale Proceeds and Declined Excess Proceeds since the Issue Date; plus

(iv) to the extent that any Restricted Investment that was made after the Issue Date is sold for cash or otherwise liquidated or repaid for cash, 100% of the aggregate amount received by the Issuer or its Restricted Subsidiaries in cash and the Fair Market Value of property other than cash received; plus

 

84


(v) the net reduction in Restricted Investments after the Issue Date resulting from dividends, liquidating distributions, redemptions, repayments of loans or advances, or other transfers of assets in each case to the Issuer or any of its Restricted Subsidiaries from any Person (including, without limitation, Unrestricted Subsidiaries and Joint Ventures) or from redesignation of Unrestricted Subsidiaries as Restricted Subsidiaries; plus

(vi) $2.0 billion,

in the case of each of the foregoing items (ii) through (v) for purposes of this clause (A), to the extent such amounts have not been included in Cumulative Distributable Cash for any period commencing on or after the Issue Date (such items (ii) through

(v) being referred to collectively as “Incremental Funds); minus

(vii) the aggregate amount of Incremental Funds previously expended pursuant to this clause (A) or clause (B) below; or

(B) if the Fixed Charge Coverage Ratio for the applicable Test Period at the time of such Restricted Payment is less than 1.75 to 1.00, such Restricted Payment, together with the aggregate amount of all other Restricted Payments made by the Issuer and its Restricted Subsidiaries during the quarter in which such Restricted Payment is made (excluding Restricted Payments permitted by clauses (2) through (19) of Section 4.07(b)) is less than the sum, without duplication, of:

(i) the greater of (x) $2.0 billion and (y) 60.0% of Distributable Cash for the applicable Test Period, less the aggregate amount of all Restricted Payments made by the Issuer and its Restricted Subsidiaries pursuant to this clause (B)(i) during the period beginning on the Issue Date and ending on the last day of the fiscal quarter immediately preceding the quarter in which such Restricted Payment is made; plus

(ii) Incremental Funds to the extent such amounts have not previously been expended pursuant to this clause (B) or clause (A) above (including any amounts that were included in Cumulative Distributable Cash for any period commencing on or after the Issue Date and expended pursuant to clause (A) above).

(b) The preceding provisions will not prohibit:

(1) the payment of any dividend or the consummation of any redemption within 60 days after the date of declaration of the dividend or giving of the redemption notice, as the case may be, if at the date of declaration or notice, the dividend or redemption payment would have complied with this Indenture;

 

85


(2) the making of any Restricted Payment in exchange for, or out of or with the net cash proceeds of the substantially concurrent sale or issuance (other than to a Subsidiary of the Issuer) of, Equity Interests of the Issuer (other than Disqualified Stock), or from the substantially concurrent contribution to the common equity capital of the Issuer (other than from a Subsidiary of the Issuer); provided that the amount of any net cash proceeds that are utilized for any such Restricted Payment will not be or not have been included in Incremental Funds;

(3) the repurchase, redemption or other acquisition or retirement for value of any Equity Interests of the Issuer held by any future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or any of its Restricted Subsidiaries pursuant to any equity subscription agreement, stock option agreement, restricted stock grant, shareholders’ agreement or similar agreement; provided that the aggregate price paid for all such repurchased, redeemed, acquired or retired Equity Interests may not exceed $50 million in any calendar year (with unused amounts in any calendar year being carried over to succeeding calendar years); and provided further, that such amount in any calendar year may be increased by an amount not to exceed the cash proceeds from (i) the sale of Equity Interests of the Issuer received by the Issuer or a Restricted Subsidiary during such calendar year, in each case to any future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or any of its Restricted Subsidiaries (to the extent not included in Incremental Funds) and (ii) key man life insurance policies received by the Issuer or any of its Restricted Subsidiaries in such calendar year;

(4) the defeasance, redemption, repurchase, repayment or other acquisition of subordinated Indebtedness with the net cash proceeds from an incurrence of Refinancing Indebtedness;

(5) the repurchase, redemption or other acquisition or retirement for value of any Preferred Stock, any Disqualified Stock or any subordinated Indebtedness pursuant to provisions similar to those described in Sections 4.10 and 4.15 hereof; provided that all Notes tendered by Holders of the Notes in connection with a Change of Control Offer or Asset Sale Offer, as applicable, have been repurchased, redeemed or acquired for value;

(6) [reserved];

(7) [reserved];

(8) the declaration and payment of regularly scheduled or accrued dividends to holders of any class or series of Disqualified Stock of the Issuer or its Restricted Subsidiaries or any Preferred Equity of any Restricted Subsidiary (other than the Issuer or the Guarantors) issued on or after the Issue Date in accordance with Section 4.09;

(9) payments of cash, dividends, distributions, advances or other Restricted Payments by the Issuer or any of its Restricted Subsidiaries to allow the payment of cash in lieu of the issuance of fractional shares upon the exercise of options, warrants or similar securities or the conversion or exchange of Capital Stock of any such Person;

 

86


(10) (i) the declaration and payment of dividends to holders of any class or series of Designated Preferred Stock (other than Disqualified Stock) issued by the Issuer after the Issue Date; provided, that for the applicable Test Period, after giving effect to such issuance or declaration on a pro forma basis, the Issuer could incur $1.00 of additional Indebtedness pursuant to Section 4.09(a); and (ii) the declaration and payment of dividends to any Parent Entity, the proceeds of which will be used to fund the payment of dividends to holders of any class or series of Designated Preferred Stock (other than Disqualified Stock) issued by such Parent Entity after the Issue Date; provided that the amount of dividends paid pursuant to this subclause (ii) shall not exceed the aggregate amount of cash actually contributed to the Issuer from the sale of such Designated Preferred Stock;

(11) the payment of any dividend (or, in the case of any partnership or limited liability company, any similar distribution) by a Restricted Subsidiary to the holders of its Equity Interests in accordance with the charter, partnership agreement, limited liability company agreement or other governing documents of such Restricted Subsidiary or on a pro rata basis or a more favorable basis to the Issuer or the Restricted Subsidiary that is the parent of the Restricted Subsidiary making such payment;

(12) any payments pursuant to clauses (19) through (21) of Section 4.11(b);

(13) additional Restricted Payments made after the Issue Date in an aggregate amount pursuant to this clause (13) not to exceed the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period;

(14) other Restricted Payments, so long as the Holdco Debt Ratio is no greater than 0.80 to 1.0 determined on a pro forma basis for the applicable Test Period; provided, however, that at the time of, and after giving effect to, any Restricted Payment permitted under this clause (14), no Event of Default shall have occurred and be continuing or would otherwise occur as a consequence thereof;

(15) the purchase by the Issuer of fractional shares arising out of stock dividends, splits or combinations or business combinations and payments or distributions to dissenting stockholders pursuant to applicable law in connection with a consolidation, merger or transfer of assets;

(16) dividends or other distributions by the Issuer or any Restricted Subsidiary of (x) Capital Stock of an Unrestricted Subsidiary, or (y) Indebtedness owed to the Issuer or a Restricted Subsidiary by, an Unrestricted Subsidiary, in each case, other than an Unrestricted Subsidiary the principal asset of which is (i) cash and Cash Equivalents or (ii) intellectual property that is material to the Issuer and its Subsidiaries, taken as a whole;

(17) any prepayment, redemption, purchase, repurchase or defeasance of Equity Interests or subordinated Indebtedness pursuant to a Permitted Transaction;

(18) (i) any prepayment, redemption, purchase, repurchase or defeasance of any Equity Interests (i) pursuant to any definitive agreement in effect as of the Issue Date and (ii) up to an additional aggregate amount pursuant to this clause (18) not to exceed $1.5 billion;

 

87


(19) the defeasance, redemption, repurchase, repayment or other acquisition of subordinated Indebtedness that constitutes a Non-Recourse Financing;

(20) (i) the declaration and payment of dividends on the common stock or common Equity Interests of the Issuer or any Parent Entity (and any equivalent declaration and payment of a distribution of any security exchangeable for such common stock or common Equity Interests to the extent required by the terms of any such exchangeable securities and any Restricted Payment to any such Parent Entity to fund the payment by such Parent Entity of dividends on such entity’s Capital Stock), following a public offering of such common stock or common Equity Interests (or such exchangeable securities, as applicable), in an amount in any fiscal year not to exceed the sum of (A) 7% of the amount of net cash proceeds received by or contributed to the Issuer or any of its Restricted Subsidiaries from any such public offering and (B) 7% of Market Capitalization; or (ii) in lieu of all or a portion of the dividends permitted by subclause (i), any prepayment, purchase, repurchase, redemption, defeasance, discharge, retirement or other acquisition of the Issuer’s Capital Stock (and any equivalent prepayment, purchase, repurchase, redemption, defeasance, discharge, retirement or other acquisition of any security exchangeable for such common stock or common equity interests to the extent required by the terms of any such exchangeable securities and any Restricted Payment to any Parent Entity to fund the prepayment, purchase, repurchase, redemption, defeasance, discharge, retirement or other acquisition of such entity’s Capital Stock) for aggregate consideration that, when taken together with dividends permitted by subclause (i), does not exceed the amount contemplated by subclause (i);

(21) Restricted Payments made in connection with or relating to, and deemed reasonably necessary by the Issuer in good faith for the consummation of, any IPO Reorganization Transactions or Tax Restructuring; provided that if immediately after giving pro forma effect to any such IPO Reorganization Transactions or Tax Restructuring and the transactions to be consummated in connection therewith, any distributed asset ceases to be owned by the Issuer or any Restricted Subsidiary (or any entity ceases to be a Restricted Subsidiary), the applicable portion of such Restricted Payment must be otherwise permitted under another provision of this covenant (and constitute utilization of such other Restricted Payment exception or capacity);

(22) payments made or expected to be made (including repurchases of Capital Stock) by the Issuer or any of its Restricted Subsidiaries in respect of withholding or similar Taxes payable in connection with the exercise or vesting of Capital Stock or any other equity award by any future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or any of its Restricted Subsidiaries or any Parent Entity and purchases, repurchases, redemptions, defeasances or other acquisitions or retirements of Capital Stock deemed to occur upon the exercise, conversion or exchange of stock options, warrants, equity-based awards or other rights in respect thereof if such Capital Stock represents a portion of the exercise price thereof or payments in respect of withholding or similar Taxes payable upon exercise or vesting thereof; and

 

88


(23) distributions or payments made directly or by means of discounts with respect to any participation interest issued or sold in connection with, and other fees paid to a Person that is not a Receivables Subsidiary in connection with, any Permitted Receivables Financing.

(c) The amount of all Restricted Payments (other than cash) shall be the Fair Market Value on the date of such Restricted Payment of the asset(s) or securities proposed to be paid, transferred or issued by the Issuer or such Restricted Subsidiary, as the case may be, pursuant to such Restricted Payment, without giving effect to subsequent changes in value. The Fair Market Value of any cash Restricted Payment shall be its face amount.

(d) For purposes of determining compliance with this Section 4.07, in the event that a proposed Restricted Payment (or a portion thereof) meets the criteria of clauses (1) through (23) of Section 4.07(b) or is entitled to be made pursuant to Section 4.07(a) or as a Permitted Investment, the Issuer will be able to classify or later reclassify (based on circumstances existing on the date of such reclassification) such Restricted Payment (or a portion thereof) between such clauses (1) through (23) of Section 4.07(b) and Section 4.07(a) or as a Permitted Investment in any manner that otherwise complies with this Section 4.07.

(e) For the avoidance of doubt, this Section 4.07 shall not restrict the making of any “AHYDO catch-up payment” with respect to, and required by the terms of, any Indebtedness of the Issuer or any of its Restricted Subsidiaries permitted to be incurred under the terms of this Indenture.

Section 4.08 Limitation on Dividends and Other Payment Restrictions Affecting Restricted Subsidiaries.

(a) The Issuer will not, and will not permit any Restricted Subsidiary to, directly or indirectly, create or otherwise cause or become effective any consensual encumbrance or restriction of any kind on the ability of any Restricted Subsidiary to:

(1) pay dividends, in cash or otherwise, or make any other distributions on or in respect of its Capital Stock or any other interest or participation in, or measured by, its profits;

(2) pay any Indebtedness owed to the Issuer or any other Restricted Subsidiary;

(3) make loans or advances to the Issuer or any other Restricted Subsidiary; or

(4) transfer any of its properties or assets to the Issuer or any other Restricted Subsidiary.

(b) Section 4.08(a) hereof will not apply to:

(1) encumbrances and restrictions existing under or by reason of the Notes, this Indenture or the Guarantees;

 

89


(2) encumbrances and restrictions existing under or by reason of (i) any agreement or instrument relating to, or entered into in connection with, any Project, any Project Obligations, any Permitted Project Undertaking, any Permitted Business Investment, any Permitted Transaction, or any Non-Recourse Financing, in each case that is not prohibited by this Indenture, or (ii) any Project Document;

(3) any encumbrance or restriction arising pursuant to an agreement or instrument relating to any Indebtedness, Disqualified Stock or Preferred Stock permitted to be incurred or issued subsequent to the Issue Date pursuant to Section 4.09 hereof if (i) such encumbrance or restriction will not materially impair the ability of the Issuer and the Guarantors, taken as a whole, to make anticipated principal or interest payments on the Notes (as determined in good faith by the Issuer), (ii) such encumbrances and restrictions are not materially more disadvantageous, taken as a whole, to the holders of the Notes than is customary in comparable financings for similarly situated issuers (as determined in good faith by the Issuer), or (iii) such encumbrances and restrictions apply only during the continuance of a default in respect of a payment or financial maintenance covenant relating to such Indebtedness, Disqualified Stock or Preferred Stock;

(4) any agreement or instrument in effect on the Issue Date;

(5) with respect to restrictions or encumbrances referred to in clause (a)(4) of this Section 4.08, encumbrances and restrictions: (i) that restrict in a customary manner the subletting, assignment or transfer of any properties or assets that are subject to a lease, license, conveyance or other similar agreement to which the Issuer or any Restricted Subsidiary is a party; and (ii) contained in Finance Lease Obligations, purchase money obligations or operating leases that impose such restrictions or encumbrances on the property so purchased, leased, expanded, constructed, developed, installed, replaced, relocated, renewed, maintained, upgraded, repaired or improved;

(6) encumbrances or restrictions contained in any agreement or other instrument of (i) a Person acquired by the Issuer or any Restricted Subsidiary in effect at the time of such acquisition or (ii) an Unrestricted Subsidiary, at the time it is designated or deemed to become a Restricted Subsidiary, in each case, which encumbrance or restriction is not applicable to any Person, or the properties or assets of any Person, other than the Person, or the property or assets of the Person, and was not put in place in contemplation of such event;

(7) encumbrances or restrictions contained in contracts for sales of Capital Stock or assets that are not prohibited by Section 4.10 with respect to the assets or Capital Stock to be sold pursuant to such contract or in customary merger or acquisition agreements (or any option to enter into such contract) for the purchase or acquisition of Capital Stock or assets or any of the Issuer’s Subsidiaries by another Person;

(8) encumbrances or restrictions existing under or by reason of applicable law, regulation or similar restriction or by governmental licenses, concessions, franchises or permits;

 

90


(9) encumbrances or restrictions on cash or other deposits or net worth imposed by customers under contracts entered into the ordinary course of business;

(10) customary provisions in joint venture agreements and other similar agreements or arrangements relating to such joint venture (as determined by the Issuer in good faith);

(11) in the case of clause (a)(4) of this Section 4.08, customary encumbrances or restrictions in connection with purchase money obligations, mortgage financings, Finance Lease Obligations and Sale and Leaseback Transactions;

(12) any encumbrance or restriction arising by reason of customary non- assignment provisions;

(13) customary restrictions on fiduciary cash held by the Issuer’s Restricted Subsidiaries;

(14) customary provisions contained in leases, sub-leases, licenses, sub-licenses or similar agreements, including with respect to intellectual property and other agreements;

(15) customary restrictions on the transfer of non-cash assets contained in power purchase agreements and similar agreements;

(16) [reserved];

(17) customary provisions in agreements governing Hedging Obligations;

(18) customary provisions contained in agreements entered into in the ordinary course of business or encumbrances or restrictions existing under or by reason of any Lien permitted to be incurred pursuant to Section 4.12;

(19) encumbrances or restrictions contained in the charter, partnership agreement or limited liability company agreement or other governing documents of a Restricted Subsidiary relating to tax equity or similar financings;

(20) any encumbrance or restriction pursuant to an agreement or instrument effecting a refunding, renewal, replacement or refinancing of Indebtedness incurred pursuant to, or that otherwise extends, renews, refunds, increases, supplements, modifies, refinances or replaces, an agreement, contract, obligation or instrument referred to in clauses (1) through (19) of this Section 4.08(b) or contained in any amendment, supplement or other modification to an agreement referred to in clauses (1) through (19) of this Section 4.08(b); provided, however, that the encumbrances and restrictions with respect to such Restricted Subsidiary contained in any such agreement or instrument (i) are not materially more restrictive, taken as a whole, with respect to such dividend and other payment restrictions than those contained in such agreement or instrument or (ii) will not materially impair the ability of the Issuer and the Guarantors, taken as a whole, to make anticipated principal or interest payments on the Notes (as determined in good faith by the Issuer); or

 

91


(21) restrictions created in connection with any Permitted Receivables Financing.

For purposes of determining compliance with this Section 4.08, (1) the priority of any Preferred Equity in receiving dividends or distributions prior to dividends or distributions being paid on common stock will not be deemed a restriction on the ability to make distributions on Capital Stock and (2) the subordination of loans or advances made to the Issuer or a Restricted Subsidiary to other Indebtedness incurred by the Issuer or any such Restricted Subsidiary will not be deemed a restriction on the ability to make loans or advances.

Section 4.09 Limitation on Indebtedness, Disqualified Stock and Preferred Equity

(a) Subject to the exceptions in Section 4.09(b), the Issuer will not, and will not permit any of its Restricted Subsidiaries to, directly or indirectly, create, incur, issue, assume, guarantee or otherwise become directly or indirectly liable, contingently or otherwise, with respect to (collectively, “incur”) any Indebtedness (including Acquired Debt), and the Issuer will not issue any Disqualified Stock and will not permit any Restricted Subsidiary to issue any Disqualified Stock or any Restricted Subsidiary that is not a Guarantor to issue Preferred Equity; provided, however, that any Recourse Person may incur Indebtedness (including Acquired Debt) or issue Disqualified Stock, and any Recourse Person (other than the Issuer) may issue Preferred Equity, if on the date of incurrence or issuance thereof the Holdco Debt Ratio for the applicable Test Period would have been equal to or less than 5.0 to 1.0, determined on a pro forma basis (including a pro forma application of the net proceeds therefrom), as if the additional Indebtedness had been incurred or the Disqualified Stock or the Preferred Equity had been issued, as the case may be, on the first day of the relevant Test Period.

(b) Section 4.09(a) will not prohibit the incurrence of any of the following items of Indebtedness (collectively, “Permitted Debt”):

(1) Indebtedness of the Issuer or any of its Restricted Subsidiaries under Credit Facilities; provided that, immediately after giving effect to any such incurrence or issuance (including pro forma application of the net proceeds therefrom), the aggregate principal amount of all such Indebtedness pursuant to this clause (1) and that is then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (1) and then outstanding) does not exceed the greater of (A) $2.0 billion and (B) 60.0% of Distributable Cash for the applicable Test Period;

(2) the incurrence by the Issuer and any Guarantor of Indebtedness represented by the Notes of each series (including any Guarantee thereof) (other than any Additional Notes, if any, or Guarantees with respect thereto);

(3) the Existing Indebtedness;

(4) Indebtedness, Disqualified Stock or Preferred Equity of the Issuer or its Restricted Subsidiaries represented by Finance Lease Obligations, Sale and Leaseback Transactions, mortgage financings or purchase money obligations, or, incurred to finance or refinance the acquisition, purchase, leasing, development, construction, repair, replacement, refurbishment, repositioning, design, installment or improvement of property

 

92


(real or personal), equipment, or other assets (including Capital Stock), and whether acquired through the direct acquisition of such property or assets or the acquisition of the Capital Stock of any Person owning such property or assets, in an aggregate outstanding principal amount as of the date of any incurrence pursuant to this clause (4) which, when taken together with the principal amount of all other Indebtedness incurred pursuant to this clause (4) and that is then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (4) and then outstanding), will not exceed the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

(5) (i) Indebtedness of the Issuer owing to any of its Restricted Subsidiaries or Indebtedness of any of its Restricted Subsidiaries owing to the Issuer or any other Restricted Subsidiary of the Issuer; provided that any such Indebtedness of the Issuer or a Guarantor owing to a Restricted Subsidiary that is not a Guarantor shall be subordinated in right of payment to the Notes; and provided further,(A) any subsequent issuance or transfer of Equity Interests that results in any such Indebtedness being held by a Person other than the Issuer or a Restricted Subsidiary and (B) any transfer of such Indebtedness to a Person that is not the Issuer or a Restricted Subsidiary will be deemed, in each case, to constitute an incurrence of such Indebtedness by the Issuer or such Restricted Subsidiary, as the case may be, that was not permitted by this clause (5); and (ii) in connection with any Indebtedness permitted by subclause (i), any such Indebtedness that is secured by a Lien on any assets or property that is required to be pledged as collateral in order to obtain or maintain any Non-Recourse Financing shall be permitted and such Indebtedness and Lien may be assigned or transferred to third party lenders providing such Non-Recourse Financing;

(6) the issuance by any of the Issuer’s Restricted Subsidiaries to the Issuer or to any of its Restricted Subsidiaries of shares of Preferred Equity; provided, however, that (A) any subsequent issuance or transfer of Equity Interests that results in any such Preferred Equity being held by a Person other than the Issuer or a Restricted Subsidiary of the Issuer, and (B) any sale or other transfer of any such Preferred Equity to a Person that is not either the Issuer or a Restricted Subsidiary of the Issuer, will be deemed, in each case, to constitute an issuance of such Preferred Equity by such Restricted Subsidiary that was not permitted by this clause (6);

(7) (x) Indebtedness or Disqualified Stock incurred or issued by the Issuer or a Restricted Subsidiary to finance an acquisition or Investment or (y) Indebtedness, Disqualified Stock or Preferred Equity of a Restricted Subsidiary incurred and outstanding on the date on which such Restricted Subsidiary was directly or indirectly acquired by the Issuer or a Restricted Subsidiary after the Issue Date or on the date it otherwise becomes a Restricted Subsidiary; provided that if, in the case of clause (x), such Indebtedness, Disqualified Stock is incurred or issued by a Recourse Person or is otherwise recourse to a Recourse Person, or in the case of clause (y), such Restricted Subsidiary is a Recourse Person or such Indebtedness, Disqualified Stock or Preferred Equity is otherwise recourse to a Recourse Person, then in each such case after giving pro forma effect to such incurrence, issuance or acquisition, as applicable, either (A) the Issuer would be permitted to incur at least $1.00 of additional Indebtedness pursuant to the Holdco Debt Ratio test set

 

93


forth in Section 4.09(a) or (B) the Holdco Debt Ratio for the applicable Test Period would be equal to or less than immediately prior to such acquisition and incurrence; and provided further, that Indebtedness, Disqualified Stock or Preferred Equity incurred or issued under this clause (7) in contemplation of such transaction will only be permitted if (i) such Restricted Subsidiary becomes a Guarantor to the extent required to do so pursuant to Section 4.16 or (ii) such Restricted Subsidiary is a Non-Recourse Subsidiary;

(8) Indebtedness of the Issuer and its Restricted Subsidiaries incurred in respect of worker’s compensation claims or claims arising under similar legislation, self-insurance or similar obligations, performance, surety and similar bonds and performance and completion guarantees provided by the Issuer and its Restricted Subsidiaries in the ordinary course of business, or consistent with past practice or industry norms (including, for the avoidance of doubt, incurred in connection with the development, financing (including refinancing), engineering, procurement, construction, commissioning, completion, operation, maintenance or insuring of any Project by any Subsidiary or any related activities to the extent incurred prior to the date of any Non-Recourse Financing by such Project);

(9) Indebtedness, Disqualified Stock and Preferred Stock of the Issuer and its Restricted Subsidiaries providing for indemnification, payment obligations in respect of any non-compete, consulting or similar arrangement, adjustment of purchase price, deferred purchase price (including adjustments thereof, contingent obligations, earn-outs and similar obligations) or progress payments for property or services, or other similar adjustments or obligations in connection with the acquisition or disposition of any business, assets or Capital Stock of a Subsidiary of the Issuer after the Issue Date;

(10) Indebtedness consisting of cash management obligations, netting services, overdraft protection and similar arrangements incurred in the ordinary course of business;

(11) (i) advance payments received from customers for goods and services purchased and credit periods in the ordinary course of business, and (ii) trade or other similar Indebtedness incurred in the ordinary course of business, which is (x) not more than ninety (90) days past due or (y) being contested in good faith and by appropriate proceedings;

(12) Indebtedness constituting reimbursement obligations with respect to letters of credit, bankers’ acceptances, discounted bills of exchange or the discounting or factoring of receivables or payables for credit management purposes, or similar instruments or obligations, in each case incurred or issued in the ordinary course of business or consistent with past practice or industry norms;

(13) Indebtedness in respect of (i) cash pooling arrangements, (ii) Bank Product Obligations and (iii) Hedging Obligations (other than Hedging Obligations incurred for speculative purposes);

 

94


(14) the guarantee by (i) the Issuer or a Restricted Subsidiary of Indebtedness (other than any Non-Recourse Financing) that is permitted to be incurred pursuant to another provision of this Section 4.09; provided that if the Indebtedness being guaranteed is subordinated to or pari passu with the Notes, then the guarantee will be subordinated or pari passu, as applicable, to the same extent as the Indebtedness guaranteed; and (ii) any Non-Recourse Subsidiary of Indebtedness of any other Non-Recourse Subsidiary to the extent such Indebtedness constitutes a Non-Recourse Financing after giving effect to such guarantee;

(15) Indebtedness in connection with any Permitted Receivables Financing;

(16) Indebtedness that constitutes Non-Recourse Financing that is incurred by a Non-Recourse Subsidiary and any Disqualified Stock and Preferred Equity issued by a Non-Recourse Subsidiary (including Disqualified Stock and Preferred Equity outstanding at the time such Non-Recourse Subsidiary becomes a Restricted Subsidiary);

(17) the guarantee by, or any other credit support from, a Recourse Person of any Non-Recourse Financing; provided that the aggregate principal amount of all Indebtedness incurred under this clause (17) and then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (17) and then outstanding) does not exceed the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

(18) Indebtedness of the Issuer or its Restricted Subsidiaries incurred pursuant to an ECR Transaction;

(19) guarantees by the Issuer or its Restricted Subsidiaries in the ordinary course of business of obligations to suppliers, customers, franchisees and licensees;

(20) Indebtedness representing deferred compensation to employees of the Issuer or any of its Restricted Subsidiaries;

(21) Indebtedness consisting of the financing of insurance premiums or take-or- pay obligations contained in supply agreements, in each case, in the ordinary course of business;

(22) Indebtedness, Disqualified Stock or Preferred Equity of the Issuer or any of its Restricted Subsidiaries in an aggregate outstanding principal amount as of the date of any incurrence pursuant to this clause (22) which, when taken together with the principal amount of all other Indebtedness incurred pursuant to this clause (22) and then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (22) that is then outstanding), will not exceed the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

(23) the guarantee by, or any other credit support from, the Issuer or any of its Restricted Subsidiaries of Indebtedness of any Unrestricted Subsidiary or any Joint Venture; provided that the aggregate principal amount of all Indebtedness incurred by any Recourse Person under this clause (23) and then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (w) and then outstanding) does not exceed the greater of (A) $500 million and (B) 15.0% of Distributable Cash for the applicable Test Period;

 

95


(24) any Refinancing Indebtedness incurred with respect to the refinancing of any Indebtedness permitted under Section 4.09(a) or clauses (1), (2), (3), (4), (7), (17), (22), (23), this (24), (25) or (30) of this Section 4.09(b);

(25) Indebtedness, Disqualified Stock and Preferred Stock represented by Management Advances;

(26) Indebtedness, Disqualified Stock or Preferred Equity of the Issuer or any Restricted Subsidiary in an aggregate principal amount or liquidation preference at any time outstanding, together with Refinancing Indebtedness in respect thereof incurred or issued pursuant to clause (x) above, not greater than 100.0% of the net cash proceeds received by the Issuer and the Restricted Subsidiaries since immediately after the Issue Date from the issue or sale of Equity Interests of the Issuer or any Parent Entity (which proceeds are contributed to the Issuer or a Restricted Subsidiary) or cash contributed to the capital of the Issuer (in each case other than proceeds of Disqualified Stock or sales of Equity Interests to, or contributions received from, the Issuer or any of its Subsidiaries) to the extent such net cash proceeds or cash have not been applied to make Restricted Payments or to make other Investments, payments or exchanges pursuant to Section 4.07(b) or to make Permitted Investments (other than Permitted Investments specified in clauses (1) and (2) of the definition thereof) and are not included in Incremental Funds;

(27) any Indebtedness representing Project Obligations or Permitted Project Undertakings;

(28) Indebtedness, Disqualified Stock and Preferred Stock incurred by the Issuer or any of its Restricted Subsidiaries to the extent that the net proceeds thereof are promptly deposited with the Trustee to satisfy or discharge the Notes or exercise the Issuer’s legal defeasance or covenant defeasance, in each case, in accordance with this Indenture;

(29) Indebtedness, Disqualified Stock and Preferred Stock arising from Permitted Intercompany Activities; and

(30) Indebtedness of the Issuer or any Guarantor that is unsecured and is expressly subordinated in right of payment to the Notes; provided, that the aggregate principal amount of all such Indebtedness incurred pursuant to this clause (30) and that is then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (30) and then outstanding) shall not exceed the greater of (A) $1.0 billion and (B) 30.0% of Distributable Cash for the applicable Test Period.

For purposes of this Indenture, no Indebtedness will be deemed to be contractually subordinated in right of payment to any other Indebtedness of the Issuer or the Guarantors solely by virtue of being unsecured or by virtue of being secured on a junior priority basis.

 

96


For purposes of determining compliance with this Section 4.09, in the event that an item of proposed Indebtedness meets the criteria of more than one of the categories described in paragraphs (b)(1) through (30) of this Section 4.09, or is entitled to be incurred in whole or in part pursuant to paragraph (a) of this Section 4.09, the Issuer will be permitted to divide and classify such item of Indebtedness on the date of its incurrence and later divide and reclassify all or a portion of such item of Indebtedness, in any manner that complies with this Section 4.09; for the avoidance of doubt, any incurrence of Indebtedness may, if applicable, be classified in part as being incurred and outstanding under the first paragraph of this covenant and in part as being incurred and outstanding under one or more categories of Permitted Debt.

(c) For purposes of determining compliance with this Section 4.09, (1) guarantees of, or obligations in respect of letters of credit, bankers’ acceptances or other similar instruments relating to, or Liens securing, Indebtedness, Disqualified Stock or Preferred Stock that is otherwise included in the determination of a particular amount of Indebtedness, Disqualified Stock or Preferred Stock shall not be included, and (2) if obligations in respect of letters of credit, bankers’ acceptances or other similar instruments are incurred pursuant to any Credit Facility and are being treated as incurred pursuant to any clause of Section 4.09(b) or Section 4.09(a) and the letters of credit, bankers’ acceptances or other similar instruments relate to other Indebtedness, Disqualified Stock or Preferred Stock, then such other Indebtedness, Disqualified Stock or Preferred Stock shall not be included.

The accrual of interest or Preferred Equity dividends, the accretion or amortization of original issue discount, the payment of interest on any Indebtedness in the form of additional Indebtedness with the same terms, the reclassification of Preferred Equity as Indebtedness due to a change in accounting principles, and the payment of dividends on Preferred Equity or Disqualified Stock in the form of additional shares of the same class of Preferred Equity or Disqualified Stock will not be deemed to be an incurrence of Indebtedness or an issuance of Preferred Equity or Disqualified Stock for purposes of this Section 4.09. For purposes of determining compliance with any U.S. dollar-denominated restriction on the incurrence of Indebtedness, the U.S. dollar-equivalent principal amount of Indebtedness denominated in a foreign currency shall be utilized, calculated based on the relevant currency exchange rate in effect on the date such Indebtedness was incurred. Notwithstanding any other provision of this Section 4.09, the maximum amount of Indebtedness that the Issuer or any Restricted Subsidiary may incur pursuant to this Section 4.09 shall not be deemed to be exceeded solely as a result of fluctuations in exchange rates or currency values. In the case of any Refinancing Indebtedness, when measuring the outstanding amount of such Indebtedness, such amount shall not include the aggregate amount of accrued and unpaid interest, dividends, premiums (including tender premiums), defeasance costs, underwriting discounts, fees, costs and expenses (including original issue discount, upfront fees or similar fees) in connection with such refinancing.

The amount of any Indebtedness outstanding as of any date will be:

(1) the accreted value of the Indebtedness, in the case of any Indebtedness issued with original issue discount;

(2) the principal amount of the Indebtedness, in the case of any other Indebtedness; and

 

97


(3) in respect of Indebtedness of another Person secured by a Lien on the assets of the specified Person, the lesser of:

(A) the Fair Market Value of such assets at the date of determination; and

(B) the amount of the Indebtedness of the other Person.

Section 4.10 Limitation on Sales of Assets.

(a) The Issuer will not, and will not permit any of its Restricted Subsidiaries to, directly or indirectly, consummate an Asset Sale unless:

(1) the Issuer (or the relevant Restricted Subsidiary, as the case may be) receives consideration at the time of the Asset Sale at least equal to the Fair Market Value of the assets or Equity Interests issued or sold or otherwise disposed of (as determined in good faith by the Issuer at the time of contractually agreeing to such Asset Sale);

(2) at least 75% of the consideration received in the Asset Sale, calculated on a cumulative basis, by the Issuer or such Restricted Subsidiary is in the form of cash or Cash Equivalents. For purposes of this provision, each of the following will be deemed to be cash:

(A) any liabilities, as recorded on the balance sheet of the Issuer or any Restricted Subsidiary (contingent or otherwise), that are assumed or discharged by the transferee (or a third party in connection with such transfer) of any such assets and as a result of which the Issuer and its Restricted Subsidiaries are no longer obliged with respect to such liabilities or are indemnified against further liabilities;

(B) any securities, notes or other obligations received by the Issuer or any such Restricted Subsidiary from such transferee that are converted by the Issuer or such Restricted Subsidiary into cash or Cash Equivalents within 180 days following the closing of the Asset Sale, to the extent of the cash or Cash Equivalents received in that conversion;

(C) any Capital Stock of any Person that will become on the date of acquisition thereof a Restricted Subsidiary as a result of such acquisition and that is involved principally in Permitted Businesses or properties and assets (other than cash or any Capital Stock or other security) that will be used in a Permitted Business of the Issuer and its Restricted Subsidiaries;

(D) Indebtedness of any Restricted Subsidiary that is no longer a Restricted Subsidiary as a result of such Asset Sale, to the extent that the Issuer and each other Restricted Subsidiary are released from any guarantee of such Indebtedness in connection with such Asset Sale;

 

98


(E) consideration consisting of Indebtedness of the Issuer or any Guarantor received from persons who are not the Issuer or any Restricted Subsidiary;

(F) any consideration consisting of Equity Interests in an entity (including a Non-Recourse Subsidiary) engaged in a Permitted Business received in connection with the sale or exchange of an Equity Interest in a Restricted Subsidiary so long as after giving effect to such transaction, the entity in which the Equity Interests have been sold or exchanged remains a Restricted Subsidiary, provided that if such Equity Interests sold or exchanged constituted Collateral the Equity Interests received as consideration constitute Collateral subsequent to such sale or exchange; and

(G) any Designated Non-cash Consideration received by the Issuer or such Restricted Subsidiary in such Asset Sale having an aggregate Fair Market Value, taken together with all other Designated Non-cash Consideration received since the Issue Date pursuant to this clause (G) that is at that time outstanding, not to exceed the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period, determined at the time of receipt of such Designated Non-cash Consideration (with the Fair Market Value of each item of Designated Non-cash Consideration being determined as of the date of receipt thereof and without giving effect to subsequent changes in value).

(b) Within 450 days after the receipt of any Net Proceeds from an Asset Sale, the Issuer (or the applicable Restricted Subsidiary, as the case may be) may:

(1) apply an amount of cash up to the Asset Sale Prepayment Percentage of such Net Proceeds (at the option of the Issuer or Restricted Subsidiary):

(A) to redeem Notes on a ratable basis as described in Section 3.07, to purchase Notes on a ratable basis through open market purchases (to the extent such purchases are at or above 100% of the principal amount thereof) or to purchase Notes pursuant to an offer to all Holders at a purchase price equal to at least 100% of the principal amount thereof, plus accrued and unpaid interest, if any, to (but not including) the date of purchase in accordance with Article 3 (a “Notes Offer”), which Notes Offer will constitute an application of the Asset Sale Prepayment Percentage of such Net Proceeds pursuant to this clause to the extent of the amount of the Notes Offer, whether or not any Notes are tendered;

(B) to the extent such Net Proceeds are from an Asset Sale of Collateral or other assets of a Recourse Person, to repurchase, prepay, redeem or repay: (i) Indebtedness of a Recourse Person that is not the Issuer or a Guarantor (other than Indebtedness owed to the Issuer or a Restricted Subsidiary), or (ii) First Lien Obligations (other than the Notes), and in the case of revolving obligations, to correspondingly reduce commitments with respect thereto; provided that in the case of clause (ii), a pro rata portion of such amount of cash is applied to redeem Notes on a ratable basis as described in Section 3.07 purchase Notes on a ratable basis through open market purchases (to the extent such purchases are at or above 100% of the principal amount thereof) or to make a Notes Offer, which Notes Offer will constitute an application of such amount of cash pursuant to this clause to the extent of the amount of the Notes Offer, whether or not any Notes are tendered;

 

99


(C) to the extent such Net Proceeds are from an Asset Sale that does not constitute Collateral or other assets of a Recourse Person: (i) to make an Investment in, or to acquire all or substantially all of the assets of, or any Capital Stock of, any Permitted Business, if, after giving effect to any such acquisition of Capital Stock, the Permitted Business is or becomes a Restricted Subsidiary (including a Non- Recourse Subsidiary), (ii) to make capital expenditures, (iii) to acquire other assets (other than Capital Stock) that are used or useful in any Project or Permitted Business, (iv) to reduce, prepay, repay or purchase any Indebtedness secured by a Lien on such asset (and terminate the related commitments if such Indebtedness is revolving Indebtedness), (v) to repurchase, prepay, redeem or repay Indebtedness of a Restricted Subsidiary that is not a Guarantor (other than Indebtedness owed to the Issuer or another Restricted Subsidiary), (vi) to repurchase, prepay, redeem or repay Senior Indebtedness (other than the Notes); provided that, in the case of this clause (vi) a pro rata portion of such amount of cash is applied to redeem Notes on a ratable basis as described under Section 3.07, purchase Notes on a ratable basis through open market purchases (to the extent such purchases are at or above 100% of the principal amount thereof) or to make a Notes Offer, which Notes Offer will constitute an application of such amount of cash pursuant to this clause to the extent of the amount of the Notes Offer, whether or not any Notes are tendered, or (vii) to repurchase, prepay, redeem or repay any Non-Recourse Financing or Indebtedness incurred pursuant to any ECR Transaction; or

(D) any combination of the foregoing; or

(2) enter into a binding commitment to apply the Asset Sale Prepayment Percentage of such Net Proceeds pursuant to clauses (1)(C)(i), (ii) or (iii) of this Section 4.10(b); provided that such binding commitment will be treated as a permitted application of the Asset Sale Prepayment Percentage of such Net Proceeds from the date of such commitment until the earlier of: (x) the date on which such acquisition or expenditure is consummated; and (y) the 180th day following the expiration of the aforementioned 450-day period.

Pending the final application of any Asset Sale Prepayment Percentage of such Net Proceeds, the Issuer (or any applicable Restricted Subsidiary) may temporarily reduce Indebtedness (including under any Credit Facility) or otherwise invest the Asset Sale Prepayment Percentage of such Net Proceeds in any manner that is not prohibited by this Indenture.

(c) Any Net Proceeds from Asset Sales (other than Retained Asset Sale Proceeds) of Collateral that are not applied or invested as provided in Section 4.10(b) hereof will constitute “Collateral Excess Proceeds.” When the aggregate amount of Collateral Excess Proceeds exceeds the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period, within ten Business Days thereof, the Issuer will make an offer (a “Collateral Asset Sale Offer”)

 

100


to all Holders on a pro rata basis and may make an offer to all holders of other First Lien Obligations to purchase, prepay or redeem the maximum principal amount of Notes on a pro rata basis and such other First Lien Obligations (plus all accrued interest on the Indebtedness and the amount of all fees and expenses, including premiums, incurred in connection therewith) that may be purchased, prepaid or redeemed out of the Collateral Excess Proceeds. The offer price for the Notes in any Collateral Asset Sale Offer will be equal to 100% of the principal amount, plus accrued and unpaid interest to the date of purchase, prepayment or redemption, subject to the rights of Holders on the relevant record date to receive interest due on the relevant Interest Payment Date, and will be payable in cash. If any Collateral Excess Proceeds remain after consummation of a Collateral Asset Sale Offer (“Declined Collateral Excess Proceeds”), the Issuer may use those Declined Collateral Excess Proceeds for any purpose not otherwise prohibited by this Indenture. If the aggregate principal amount of Notes and other Additional First Lien Obligations tendered into (or to be prepaid or redeemed in connection with) such Collateral Asset Sale Offer exceeds the amount of Collateral Excess Proceeds or if the aggregate amount of the Notes tendered pursuant to a Notes Offer exceeds the amount of the Net Proceeds so applied, such Notes and such other First Lien Obligations, if applicable, will be purchased on a pro rata basis, based on the amounts tendered or required to be prepaid or redeemed (with such adjustments as may be deemed appropriate by the Issuer so that only Notes in denominations of $2,000, or an integral multiple of $1,000 in excess thereof, will be purchased). Upon completion of each Collateral Asset Sale Offer, the amount of Collateral Excess Proceeds will be reset at zero. The Issuer may satisfy the foregoing obligations with respect to any Net Proceeds from an Asset Sale by making a Collateral Asset Sale Offer with respect to such Net Proceeds prior to the time period that may be required by this Indenture with respect to all or a part of the available Net Proceeds (the “Collateral Advance Portion”) in advance of being required to do so by this Indenture (a “Collateral Advance Offer”).

(d) Any Net Proceeds from Asset Sales (other than Retained Asset Sale Proceeds) that do not constitute Collateral that are not applied or invested as provided in Section 4.10(b) hereof will constitute “Excess Proceeds.” When the aggregate amount of Excess Proceeds exceeds the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period, within ten Business Days thereof, the Issuer will make an offer (an “Asset Sale Offer”) to all Holders on a pro rata basis and may make an offer to all holders of other Senior Indebtedness to purchase, prepay or redeem the maximum principal amount of Notes on a pro rata basis and such other Senior Indebtedness (plus all accrued interest on the Indebtedness and the amount of all fees and expenses, including premiums, incurred in connection therewith) that may be purchased, prepaid or redeemed out of the Excess Proceeds. The offer price for the Notes in any Asset Sale Offer will be equal to 100% of the principal amount, plus accrued and unpaid interest to the date of purchase, prepayment or redemption, subject to the rights of Holders on the relevant record date to receive interest due on the relevant Interest Payment Date, and will be payable in cash. If any Excess Proceeds remain after consummation of an Asset Sale Offer (“Declined Non-Collateral Excess Proceeds” and, together with the Declined Collateral Excess Proceeds, “Declined Excess Proceeds”), the Issuer may use those Declined Non-Collateral Excess Proceeds for any purpose not otherwise prohibited by this Indenture. If the aggregate principal amount of Notes and other Senior Indebtedness tendered into (or to be prepaid or redeemed in connection with) such Asset Sale Offer exceeds the amount of Excess Proceeds or if the aggregate amount of the Notes tendered pursuant to a Notes Offer exceeds the amount of the Net Proceeds so applied, such Notes and such other Senior Indebtedness, if applicable, will be purchased on a pro rata basis, based on the amounts tendered or required to be prepaid or redeemed (with such adjustments as may be deemed

 

101


appropriate by the Issuer so that only Notes in denominations of $2,000, or an integral multiple of $1,000 in excess thereof, will be purchased). Upon completion of each Asset Sale Offer, the amount of Excess Proceeds will be reset at zero. The Issuer may satisfy the foregoing obligations with respect to any Net Proceeds from an Asset Sale by making an Asset Sale Offer with respect to such Net Proceeds prior to the time period that may be required by this Indenture with respect to all or a part of the available Net Proceeds (the “Advance Portion”) in advance of being required to do so by this Indenture (a “Advance Offer”).

(e) The Issuer will comply with the requirements of Rule 14e-1 under the Exchange Act and any other securities laws and regulations thereunder to the extent those laws and regulations are applicable in connection with each repurchase of Notes pursuant to an Asset Sale Offer. To the extent that the provisions of any securities laws or regulations conflict with the provisions of Section 3.09 hereof or this Section 4.10, the Issuer will comply with the applicable securities laws and regulations and will not be deemed to have breached its obligations under Section 3.09 hereof or this Section 4.10 by virtue of such compliance.

(f) The provisions of Section 3.09 and this Section 4.10 may be waived or modified with the written consent of the Holders of a majority in aggregate principal amount of all the then outstanding Notes.

Section 4.11 Limitation on Transactions with Affiliates.

(a) The Issuer will not, and will not permit any Restricted Subsidiary to, directly or indirectly, enter into or suffer to exist any transaction or series of related transactions (including, without limitation, the sale, purchase, exchange or lease of assets or property or the rendering of any service) with, or for the benefit of, any Affiliate of the Issuer or any Restricted Subsidiary involving aggregate payments or consideration in excess of the greater of (A) $75 million and (B) 2.0% of Distributable Cash for the applicable Test Period (each, an “Affiliate Transaction”), unless:

(1) such transaction or series of transactions is on terms that, taken as a whole, are not materially less favorable to the Issuer or such Restricted Subsidiary, as the case may be, than those that would have been obtained in a comparable transaction at such time on an arm’s-length basis with third parties that are not Affiliates, or, if in the good faith judgment of the Issuer, no comparable transaction is available with which to compare such Affiliate Transaction, such Affiliate Transaction is otherwise fair to the Issuer or such Restricted Subsidiary from a financial point of view and when such transaction is taken in its entirety; and

(2) with respect to any transaction or series of related transactions involving aggregate payments or the transfer of assets or the provision of services, in each case having a value that exceeds the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period, the Issuer’s Board of Directors must approve such transaction (including a majority of the disinterested directors).

(b) Notwithstanding the foregoing, the restrictions set forth in Section 4.11(a) will not apply to:

 

102


(1) customary directors’ fees and expenses, indemnities and similar arrangements (including the payment of directors’ and officers’ insurance premiums), consulting fees, employee compensation, employee and director bonuses, employment agreements and arrangements or employee benefit arrangements, including stock options or legal fees, as determined in good faith by the Issuer;

(2) Permitted Investments and Restricted Payments that are permitted by Section 4.07 (including any transaction that would otherwise constitute a Restricted Payment but is expressly excluded from the definition of the term “Restricted Payments”);

(3) any Management Advances and any waiver or transaction with respect thereto;

(4) agreements and arrangements existing on the Issue Date, and the performance by the Issuer or any Restricted Subsidiary of their obligations thereunder and any amendments, modifications, replacements or supplements thereto or similar agreements entered into in the future; provided that any such amendments, modifications, replacements or supplements, taken as a whole, or any such similar agreements, are not more disadvantageous to the Holders in any material respect than the original agreements or arrangements as in effect on the Issue Date (as determined by the Issuer in good faith) or as are not otherwise prohibited by this Section 4.11;

(5) the issuance of securities pursuant to, or for the purpose of the funding of, employment, termination or severance arrangements, stock options and stock ownership plans, as long as the terms thereof are or have been previously approved by the Issuer’s or the relevant Restricted Subsidiary’s Board of Directors;

(6) (i) transactions between or among, or for the benefit of, the Issuer and the Restricted Subsidiaries (or entity that becomes a Restricted Subsidiary as a result of such transaction), or between or among Restricted Subsidiaries, and (ii) any merger, amalgamation or consolidation with any Parent Entity, provided that, in the case of this clause (ii), such Parent Entity shall have no material liabilities and no material assets other than cash, Cash Equivalents and the Capital Stock of the Issuer and such merger, amalgamation or consolidation is otherwise not prohibited under this Indenture;

(7) payments to or from, and transactions with, customers, clients, suppliers or purchasers or sellers of goods or services, or transactions otherwise relating to the purchase or sale of goods or services (including any cash management activities related thereto), in each case in the ordinary course of business or consistent with past practice or industry norms, or that are on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable as might reasonably have been obtained at such time from an unaffiliated party, in each case as determined by the Issuer in good faith;

(8) any issuance of Equity Interests (other than Disqualified Stock) of the Issuer;

(9) the pledge of Equity Interests of Unrestricted Subsidiaries;

 

103


(10) any contribution to the capital of the Issuer;

(11) transactions with respect to which the Issuer has obtained an opinion as to the fairness to the Issuer and its Restricted Subsidiaries from a financial point of view issued by an accounting, appraisal or investment banking firm of national standing;

(12) transactions permitted by, and complying with, the provisions of, Article 5;

(13) transactions with (i) Unrestricted Subsidiaries or (ii) Joint Ventures in which the Issuer or a Subsidiary of the Issuer holds or acquires an ownership interest (whether by way of Capital Stock or otherwise) or any partners of any such Joint Venture, in each case entered into in the ordinary course or business or consistent with past practice or industry norms (including, without limitation, any cash management activities related thereto), or that are on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable to the Issuer or the applicable Restricted Subsidiary as might reasonably have been obtained at such time from an unaffiliated party (as determined by the Issuer in good faith);

(14) transactions between the Issuer or any of its Restricted Subsidiaries and any Person that is an Affiliate solely as a result of the ownership by the Issuer or any of the Restricted Subsidiaries of Capital Stock of such Person;

(15) transactions with Persons solely in their capacity as holders of Indebtedness of the Issuer or any of its Restricted Subsidiaries where such Persons are treated no more favorably than holders of Indebtedness of the Issuer or such Restricted Subsidiaries generally;

(16) transactions entered into by an Unrestricted Subsidiary with an Affiliate prior to the time such Unrestricted Subsidiary becomes a Restricted Subsidiary;

(17) (i) investments by Affiliates in securities or loans or other Indebtedness of the Issuer or any of its Restricted Subsidiaries (and payment of out-of-pocket expenses incurred by such Affiliates in connection therewith) so long as the investment is being offered by the Issuer or such Restricted Subsidiary generally to other investors on the same or more favorable terms, and (ii) payments to Affiliates in respect of securities or loans or other Indebtedness of the Issuer or any of its Restricted Subsidiaries contemplated in the foregoing subclause (i) or that were acquired from Persons other than the Issuer and its Restricted Subsidiaries, in each case, in accordance with the terms of such securities or loans;

(18) transfers of leases, servitudes or similar assets and the entry into related license agreements, in each case, in the ordinary course of business or consistent with past practice or industry norms;

(19) any lease entered into between the Issuer or any Restricted Subsidiary, as lessee, and any Affiliate of the Issuer, as lessor, in each case entered into in the ordinary course of business or consistent with past practice or industry norms, or that is on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable as might reasonably have been obtained at such time from an unaffiliated party, in each case as determined by the Issuer in good faith;

 

104


(20) any administrative services agreement, operations and maintenance agreement, marketing agreement, charter agreement, shipping agency agreement, reciprocal services agreement, excess capacity offtake agreement (including any sale and purchase agreement entered into in connection therewith) or other similar agreement or arrangement with the VGP Investor or any of its Affiliates relating to, or otherwise entered into in connection with, any Project or Permitted Business, in each case entered into in the ordinary course or business or consistent with past practice or industry norms, or that are on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable to the Issuer or the applicable Restricted Subsidiary as might reasonably have been obtained at such time from an unaffiliated party, in each case as determined by the Issuer in good faith;

(21) payments by the Issuer or any Restricted Subsidiary (including any payment to any Parent Entity for further payment by such Parent Entity), (A) to reimburse the VGP Investor and any of its Affiliates and designees for any reasonable or customary out-of- pocket costs and expenses incurred in connection with the provision of any management, advisory, consulting or other similar services, and (B) to pay reasonable or customary management, monitoring, consulting and similar fees to the VGP Investor; provided that, in the case of the foregoing subclause (B), no such payments shall be made if an Event of Default shall have occurred and be continuing or would immediately result after giving pro forma effect to such payments (it being agreed that such amounts may accrue, but not be payable in cash during such period; provided that all such accrued amounts (plus accrued interest, if any, with respect thereto) may be payable in cash upon the cure or waiver of such Event of Default);

(22) the existence of, or the performance by the Issuer or any of its Restricted Subsidiaries of its obligations under the terms of, any stockholders agreement (including any registration rights agreement or purchase agreement relating thereto) in effect as of the Issue Date and any amendments, modifications, replacements or supplements thereto or similar agreements entered into in the future; provided that any such amendments, modifications, replacements or supplements, taken as a whole, or any such similar agreements, are not more disadvantageous to the holders of the Notes in any material respect than the original agreements or arrangements as in effect on the Issue Date (as determined by the Issuer in good faith) or as are not otherwise prohibited by this Section 4.11;

(23) any transactions with any Captive Insurance Subsidiary;

(24) any Project Obligations, Permitted Project Undertakings and ECR Transactions;

(25) any Permitted Intercompany Activities, any IPO Reorganization Transactions, any Tax Restructuring, and related transactions; and

 

105


(26) sales of accounts receivable, or participations therein, or accounts receivable, royalty or other revenue streams and other rights to payment and any other assets, or other transactions, in connection with any Permitted Receivables Financing.

Section 4.12 Limitation on Liens.

(a) The Issuer will not, and will not permit any of its Restricted Subsidiaries to create, any Lien upon the whole or any part of the currently owned or after-acquired property of the Issuer or any of its Restricted Subsidiaries or assets (each, a “Subject Lien”) to secure any Indebtedness or any guarantee or indemnity in respect of any Indebtedness (other than Permitted Liens), unless, in the case of any Subject Lien on any asset or property that is not Collateral, the Notes (or a Guarantee in the case of Subject Liens on assets or property of a Guarantor) are equally and ratably secured with (or on a senior basis to, in the case such Subject Lien secures any Subordinated Indebtedness) the Obligations secured by such Subject Lien until such time as such Obligations are no longer secured by such Subject Lien.

(b) Any Lien created for the benefit of the holders of the Notes pursuant to this Section 4.12 shall be deemed automatically and unconditionally released and discharged upon the release and discharge of the Subject Lien that gave rise to the obligation to secure the Notes. In addition, in the event that a Subject Lien is or becomes a Permitted Lien, the Issuer may, at its option and without consent from any holder of the Notes, elect to release and discharge any Lien created for the benefit of the holders pursuant to Section 4.12(a) in respect of such Subject Lien.

(c) With respect to any Lien securing Indebtedness that was permitted to secure such Indebtedness at the time of the Incurrence of such Indebtedness, such Lien shall also be permitted to secure any Increased Amount of such Indebtedness. The “Increased Amount” of any Indebtedness shall mean any increase in the amount of such Indebtedness in connection with any accrual of interest, the accretion of accreted value, the amortization of original issue discount, the payment of interest in the form of additional Indebtedness with the same terms, accretion of original issue discount or liquidation preference and increases in the amount of Indebtedness outstanding solely as a result of fluctuations in the exchange rate of currencies or increases in the value of property securing Indebtedness.

Section 4.13 [Reserved].

Section 4.14 Corporate Existence.

Subject to Article 5 hereof, the Issuer shall do or cause to be done all things necessary to preserve and keep in full force and effect its existence, and the corporate, partnership, limited liability company or other existence of each of its Restricted Subsidiaries, in accordance with the respective organizational documents (as the same may be amended from time to time) of the Issuer or any such Restricted Subsidiary; provided that the Issuer shall not be required to preserve the corporate, partnership or other existence of its Restricted Subsidiaries, if the Issuer in good faith shall determine that the preservation thereof is no longer desirable in the conduct of the business of the Issuer and its Restricted Subsidiaries, taken as a whole. For the avoidance of doubt, the Issuer and its Restricted Subsidiaries will be permitted to change their organizational form.

 

106


Section 4.15 Offer to Repurchase Upon Change of Control Triggering Event.

(a) Upon the occurrence of a Change of Control Triggering Event with respect to any series of Notes, the Issuer will be required to make an offer (a “Change of Control Offer”) to each Holder of Notes of such series to repurchase all or any part (being not less than $2,000 or an integral multiple of $1,000 in excess thereof) of that Holder’s Notes of such series pursuant to the terms set forth in this Section 4.15.

(b) In the Change of Control Offer, the Issuer will offer a payment in cash (the “Change of Control Payment”) equal to 101% of the aggregate principal amount of Notes of the applicable series repurchased, plus accrued and unpaid interest, if any, on the Notes repurchased to, but not including, the date of purchase (the “Change of Control Payment Date”), subject to the rights of Holders on the relevant record date to receive interest, if any, due on the relevant Interest Payment Date. Within 30 days following any Change of Control Triggering Event, the Issuer will mail, or deliver electronically if the Notes of the applicable series are held at DTC, a notice to each Holder describing the transaction or transactions that constitute the Change of Control Triggering Event and offering to repurchase such Notes on the Change of Control Payment Date specified in the notice, which date will be no earlier than 30 days and no later than 60 days from the date such notice is mailed or electronically delivered, pursuant to the procedures required by this Indenture and described in such notice, except in the case of a conditional Change of Control Offer made in advance of a Change of Control as described below. The Issuer will comply with the requirements of Rule 14e-1 under the Exchange Act and any other securities laws and regulations thereunder to the extent those laws and regulations are applicable in connection with the repurchase of the Notes of the applicable series as a result of a Change of Control Triggering Event. To the extent that the provisions of any securities laws or regulations conflict with this Section 4.15, the Issuer will comply with the applicable securities laws and regulations and will not be deemed to have breached its obligations in this Section 4.15 by virtue of such compliance. The Issuer may rely on any no-action letters issued by the Commission indicating that the staff of the Commission will not recommend enforcement action in the event a tender offer satisfies certain conditions.

(c) On the Change of Control Payment Date, the Issuer will, to the extent lawful:

(1) accept for payment all Notes or portions of Notes properly tendered pursuant to the Change of Control Offer;

(2) deposit with the Paying Agent an amount equal to the Change of Control Payment in respect of all Notes or portions of Notes properly tendered; and

(3) deliver or cause to be delivered to the Trustee the Notes properly accepted together with an Officer’s Certificate stating the aggregate principal amount of Notes or portions of Notes being purchased by the Issuer.

The Paying Agent will promptly deliver to each Holder of Notes properly tendered the Change of Control Payment for such Notes(or, if all the Notes are then in global form, make such payment through the facilities of DTC), and, for any Notes represented by certificated notes, the Trustee will, upon receipt of an Authentication Order, promptly authenticate and mail (or cause to be transferred by book entry) to such Holder a new certificated note representing equal in principal amount to any unpurchased portion of the Notes surrendered, if any; provided that each such new Note will be in a principal amount of not less than $2,000 or an integral multiple of $1,000 in excess thereof. Any Note so accepted for payment will cease to accrue interest on and after the Change of Control Payment Date unless the Issuer defaults in making the Change of Control Payment. The Issuer will publicly announce the results of the Change of Control Offer on or as soon as practicable after the Change of Control Payment Date.

 

107


(d) The provisions described herein that require the Issuer to make a Change of Control Offer following a Change of Control Triggering Event will be applicable regardless of whether any other provisions of this Indenture are applicable.

(e) The Issuer will not be required to make a Change of Control Offer upon a Change of Control Triggering Event if (1) a third party makes the Change of Control Offer in the manner, at the times and otherwise in compliance with the requirements set forth in this Indenture applicable to a Change of Control Offer made by the Issuer and purchases all Notes properly tendered and not withdrawn under the Change of Control Offer, or (2) a notice of redemption with respect to the Notes of the applicable series has been given pursuant to this Indenture as described in Section 3.07 and all conditions to any such redemption shall have been satisfied or waived, unless and until there is a default in payment of the Change of Control Payment. A Change of Control Offer may be made in advance of a Change of Control or a Change of Control Triggering Event, and conditioned upon the occurrence of such Change of Control or Change of Control Triggering Event, if a definitive agreement is in place for a Change of Control at the time of making the Change of Control Offer, Notes repurchased by the Issuer pursuant to a Change of Control Offer will have the status of Notes issued but not outstanding or will be retired and cancelled, at the Issuer’s option. Notes purchased by a third party pursuant to this clause (e) will have the status of Notes issued and outstanding.

The provisions in this Section 4.15 relating to the Issuer’s obligation to make an offer to repurchase the Notes of any series as a result of a Change of Control may be waived or modified with the written consent of the Holders of a majority in aggregate principal amount of the Notes of such series then outstanding.

The Trustee shall have no obligation to determine whether a Change of Control Triggering Event or any component thereof has occurred or is continuing, or notify the Holders of a Change of Control Triggering Event.

Section 4.16 Future Guarantees.

If, on any date (a “Guarantee Date”), the aggregate amount of Indebtedness for borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit of any Restricted Subsidiary that is not a Guarantor or a Non-Recourse Subsidiary then outstanding (other than any such Indebtedness owing to the Issuer or any Guarantor) exceeds the greater of (A) $250.0 million and (B) 7.5% of Distributable Cash for the applicable Test Period (tested at the time of incurrence of the applicable Indebtedness without regard to any subsequent change in Distributable Cash), the Issuer will cause such Restricted Subsidiary to (x) execute and deliver to the Trustee, within 45 days after such Guarantee Date, a supplemental indenture to this Indenture, which shall be substantially in the form attached as Exhibit E hereto, pursuant to which such Restricted Subsidiary will unconditionally guarantee the payment of the Notes, jointly and severally with all other Guarantors (if any) of the Notes, and (y) execute and deliver Security Documents or supplements thereto.

 

108


Section 4.17 Designation of Restricted and Unrestricted Subsidiaries.

(a) The Board of Directors of the Issuer may designate any Subsidiary of the Issuer (including any newly acquired or newly formed Subsidiary or a Person becoming a Subsidiary through merger, consolidation or other business combination transaction, or Investment therein), to be an Unrestricted Subsidiary only if:

(1) such Subsidiary or any of its Subsidiaries does not own any Equity Interests or Indebtedness of, or own or hold any Lien on any property of, the Issuer or any other Subsidiary of the Issuer which is not a Subsidiary of the Subsidiary to be so designated or otherwise an Unrestricted Subsidiary; provided that each Subsidiary to be so designated and its Subsidiaries has not at the time of designation, and does not thereafter, create, incur, issue, assume, guarantee or otherwise become directly or indirectly liable with respect to any Indebtedness pursuant to which the lender has recourse to any of the assets of the Issuer or any Restricted Subsidiary (other than Equity Interests in the Unrestricted Subsidiary); and

(2) such designation and the Investment of the Issuer or any of the Restricted Subsidiaries in such Subsidiary complies with Section 4.07.

Any such designation by the Board of Directors of the Issuer shall be evidenced to the Trustee by filing with the Trustee a copy of the resolution of the Board of Directors of the Issuer giving effect to such designation and an Officer’s Certificate certifying that such designation complies with the foregoing conditions.

(b) The Board of Directors of the Issuer may designate any Unrestricted Subsidiary to be a Restricted Subsidiary; provided that immediately after giving effect to such designation (1) no Event of Default would result therefrom and (2) (a) any outstanding Indebtedness of such Unrestricted Subsidiary would be permitted to be incurred by a Restricted Subsidiary under Section 4.09 and shall be deemed to be incurred thereunder, and (b) all Liens encumbering the assets of such Unrestricted Subsidiary would be permitted to be incurred by a Restricted Subsidiary under Section 4.12 and shall be deemed to be incurred thereunder, in each case calculated on a pro forma basis as if such designation had occurred at the beginning of the applicable reference period on a pro forma basis taking into account such designation. Any such designation by the Board of Directors of the Issuer shall be evidenced to the Trustee by promptly filing with the Trustee a copy of the resolution of the Board of Directors giving effect to such designation or an Officer’s Certificate certifying that such designation complied with the foregoing provisions.

Section 4.18 Suspension of Certain Covenants.

If on any date following the Issue Date:

(a) the Notes of any series have an Investment Grade Rating from at least one Rating Agency; and

 

109


(b) no Event of Default shall have occurred and be continuing under this Indenture (the occurrence of the events described in the foregoing clauses (1) and (2) being collectively referred to as a “Covenant Suspension Event”),

then, beginning on that day and subject to the provisions of the following paragraph, the covenants of this Indenture under Sections 4.07, 4.08, 4.09, 4.10, 4.11, 4.16, clause (4) of Section 5.01 and Article 12 will be suspended (the “Suspended Covenants”) with respect to the Notes of such series:

During any period that the foregoing covenants have been suspended with respect to a series of Notes, the Board of Directors of the Issuer may not designate any of the Issuer’s Subsidiaries as Unrestricted Subsidiaries with respect to the Notes of such series.

During the Suspension Period with respect to any series of Notes, the Issuer and its Restricted Subsidiaries will be entitled to incur Liens to the extent provided for in Section 4.12 (including, without limitation, Permitted Liens). Any Permitted Liens that may refer to one or more Suspended Covenants shall be interpreted as though such applicable Suspended Covenant(s) continued to be applicable during the Suspension Period (but solely for purposes of Section 4.12 and the “Permitted Liens” definition and for no other covenant).

Notwithstanding the foregoing, if a Rating Agency withdraws its ratings or downgrades the ratings assigned to the Notes of a series such that the Notes of such series no longer have an Investment Grade Rating from at least one Rating Agency, the foregoing covenants shall be reinstated as of and from the date of such rating decline (the “Reversion Date”) with respect to the Notes of such series. The period of time between the Covenant Suspension Event and the Reversion Date with respect to an applicable series of Notes is referred to in this Indenture as the “Suspension Period” and shall relate solely to such series of Notes. Any Indebtedness incurred during the Suspension Period (or deemed incurred or issued in connection with a Limited Condition Transaction entered into during the Suspension Period) will be classified as having been incurred pursuant to clause (3) of Section 4.09(b) with respect to the applicable series of Notes.

Solely with respect to any series of Notes for which a Covenant Suspension Event has occurred:

(1) Calculations made after the Reversion Date of the amount available to be made as Restricted Payments under Section 4.07 will be made as though Section 4.07 had been in effect since the Issue Date and prior to, but not during, the Suspension Period (including with respect to a Limited Condition Transaction entered into during the Suspension Period). Accordingly, Restricted Payments made during the Suspension Period will not reduce the amount available to be made as Restricted Payments under Section 4.07(a). In addition, all Investments made during the Suspension Period (or deemed made in connection with a Limited Condition Transaction entered into during the Suspension Period) will be classified to have been made under clause (5) of the definition of “Permitted Investments”;

(2) For purposes of Section 4.08, on the Reversion Date, any consensual encumbrances or consensual restrictions of the type specified in clauses (1) through (4) of Section 4.08(a) entered into during the Suspension Period will be deemed to have been in effect on the Issue Date, so that they are permitted under clause (4) of Section 4.08(b);

 

110


(3) For purposes of Section 4.11, any Affiliate Transaction entered into after the Reversion Date pursuant to a contract, agreement, loan, advance or guaranty with, or for the benefit of, any Affiliate of the Issuer entered into during the Suspension Period will be deemed to have been in effect as of the Issue Date for purposes of clause (4) of Section 4.11(b);

(4) For purposes of Section 4.10, the amount of Collateral Excess Proceeds and Excess Proceeds will be reset at zero; and

(5) Notwithstanding that the Suspended Covenants may be reinstated after the Reversion Date, (a) no Default, Event of Default or breach of any kind will be deemed to exist under this Indenture, the Notes or the Guarantees with respect to the Suspended Covenants, and none of the Issuer or any of its Subsidiaries shall bear any liability for any actions taken or events occurring during the Suspension Period, or any actions taken at any time pursuant to any Contractual Obligation arising during any Suspension Period, in each case as a result of a failure to comply with the Suspended Covenants during the Suspension Period (or, upon termination of the Suspension Period or after that time based solely on any action taken or event that occurred during the Suspension Period), and (b) following a Reversion Date, the Issuer and each Restricted Subsidiary will be permitted, without causing a Default or Event of Default, to honor, comply with or otherwise perform any contractual commitments or obligations arising during any Suspension Period and to consummate the transactions contemplated thereby.

Promptly following the occurrence of any Suspension Period or Reversion Date in accordance with this Section 4.18, the Issuer will provide an Officer’s Certificate to the Trustee regarding such occurrence, provided that the failure to so notify the Trustee shall not be a default under this Indenture. The Trustee shall have no obligation to independently determine or verify if a Suspension Period or Reversion Date has occurred or notify the holders of any Suspension Period or Reversion Date. The Trustee may provide a copy of such Officer’s Certificate to any Holder upon request. The Trustee shall have no duty to monitor the ratings of the Notes, and shall not be deemed to have any knowledge of the ratings of the Notes.

ARTICLE 5

SUCCESSORS

Section 5.01 Merger, Consolidation or Sale of Assets.

(a) The Issuer will not, directly or indirectly: (1) consolidate or merge with or into another Person (whether or not the Issuer is the surviving Person); or (2) sell, assign, transfer, convey or otherwise dispose of all or substantially all of the properties or assets of the Issuer and its Subsidiaries, taken as a whole, in one or more related transactions, to another Person; unless:

(1) either: (a) the Issuer is the surviving Person; or (b) the Person formed by or surviving any such consolidation or merger (if other than the Issuer) or to which such sale, assignment, transfer, conveyance or other disposition has been made is a corporation, partnership or limited liability company organized or existing under the laws of the United States, any state of the United States or the District of Columbia;

 

111


(2) the Person formed by or surviving any such consolidation or merger (if other than the Issuer) or the Person to which such sale, assignment, transfer, conveyance or other disposition has been made assumes all the obligations of the Issuer under the Security Documents, the Notes and this Indenture pursuant to a supplemental Indenture or other customary documentation;

(3) immediately after such transaction, no Event of Default exists;

(4) the Issuer, as the case may be, or the Person formed by or surviving any such consolidation or merger (if other than the Issuer), or to which such sale, assignment, transfer, conveyance or other disposition has been made would, on the date of such transaction after giving pro forma effect thereto and any related financing transactions as if the same had occurred at the beginning of the applicable Test Period, (i) be permitted to incur at least $1.00 of additional Indebtedness pursuant to the Holdco Debt Ratio test set forth in Section 4.09(a) or (ii) would have had a Holdco Debt Ratio equal to or less than the actual Holdco Debt Ratio for the applicable Test Period;

(5) the Issuer delivers to the Trustee an Officer’s Certificate and opinion of counsel as to compliance with this Section 5.01(a); and

(6) to the extent any assets of the Person formed by or surviving any such consolidation or merger are assets of the type which would constitute Collateral under the Security Documents, such Person will take such action as may be reasonably necessary to cause such property and assets to be made subject to the Lien of the Security Documents in the manner and to the extent required in this Indenture or any of the Security Documents and shall take all reasonably necessary action required by this Indenture of any of the Security Documents so that such Lien is perfected to the extent required by the Security Documents.

In addition, the Issuer may not, directly or indirectly, lease all or substantially all of its and its respective Subsidiaries’ properties or assets, in one or more related transactions, to any other Person.

This Section 5.01(a) will not apply to (1) a merger of the Issuer with an Affiliate solely for the purpose of reforming the Issuer in another jurisdiction; (2) any sale, transfer, assignment, conveyance, lease or other disposition of assets between or among the Issuer and any Restricted Subsidiary of the Issuer, including by way of merger or consolidation; (3) a conversion by the Issuer into a corporation, partnership, limited partnership, limited liability company or trust organized or existing under the laws of the jurisdiction of organization of the Issuer or the laws of a jurisdiction in the United States (and, if such entity is not a corporation, a co-obligor of the Notes is a corporation organized or existing under such laws); and (4) a change of the Issuer’s name.

 

112


(b) Subject to Section 10.04, no Guarantor will, and the Issuer will not permit any Guarantor to, consolidate or merge with or into or wind up into (whether or not such Guarantor is the surviving Person), or sell, assign, transfer, lease, convey or otherwise dispose of all or substantially all of its properties or assets, in one or more related transactions, to any Person unless:

(1) either: (a) such Guarantor is the surviving Person; or (b) the Person formed by or surviving any such consolidation or merger (if other than such Guarantor) or the Person to which such sale, assignment, transfer, conveyance or other disposition has been made assumes all the obligations of such Guarantor under the Security Documents, the Notes, this Indenture and such Guarantor’s related Guarantee pursuant to supplemental indenture or other customary documentation;

(2) immediately after such transaction, no Event of Default exists;

(3) the Issuer delivers to the Trustee an Officer’s Certificate and an Opinion of Counsel as to compliance with this Section 5.01(b); and

(4) to the extent any assets of the Person formed by or surviving any such consolidation or merger are assets of the type which would constitute Collateral under the Security Documents, such Person will take such action as may be reasonably necessary to cause such property and assets to be made subject to the Lien of the Security Documents in the manner and to the extent required in this Indenture or any of the Security Documents and shall take all reasonably necessary action required by this Indenture of any of the Security Documents so that such Lien is perfected to the extent required by the Security Documents; or

(A) the transaction is not prohibited by Section 4.10(a); or

(B) in the case of assets comprised of Equity Interests of Subsidiaries that are not Guarantors, such Equity Interests are sold, assigned, transferred, leased, conveyed or otherwise disposed of to one or more Restricted Subsidiaries, provided that if such Equity Interests constitute Collateral they will continue to constitute Collateral following such disposition.

This Section 5.01(b) will not apply to (1) a merger of the Guarantor with an Affiliate solely for the purpose of reforming the Guarantor in another jurisdiction, (2) any sale, transfer, assignment, conveyance, lease or other disposition of assets between or among the Issuer or a Guarantor, (3) a conversion by the Guarantor into a corporation, partnership, limited partnership, limited liability company or trust organized or existing under the laws of the jurisdiction of organization of such Guarantor, or (4) a liquidation or dissolution or change of the Guarantor’s legal form if the Issuer determines in good faith that such action is in the best interests of the Issuer, in each case, without regard to the requirements set forth in the preceding paragraph.

Section 5.02 Successor Corporation Substituted

Upon any consolidation or merger, or any sale, assignment, transfer, lease, conveyance or other disposition of all or substantially all of the properties or assets of the Issuer or any Guarantor in a transaction that is subject to, and that complies with the provisions of, Section 5.01 hereof, the successor Person formed by such consolidation or into or with which the Issuer or such Guarantor, as the case may be, is merged or to which such sale, assignment, transfer, lease, conveyance or

 

113


other disposition is made shall succeed to, and be substituted for (so that from and after the date of such consolidation, merger, sale, assignment, transfer, lease, conveyance or other disposition, the provisions of this Indenture referring to the “Issuer” or such “Guarantor” shall refer instead to the successor Person and not to the Issuer or such Guarantor), and may exercise every right and power of the Issuer or such Guarantor, as the case may be, under this Indenture or the Guarantees, as the case may be, with the same effect as if such successor Person had been named as the Issuer or such Guarantor, as the case may be, herein or the Guarantees, as the case may be. When a successor Person assumes all obligations of its predecessor hereunder, the Notes or the Guarantees, as the case may be, such predecessor shall be released from all obligations; provided that in the event of a transfer or lease, the predecessor shall not be released from the payment of principal and interest or other obligations on the Notes or the Guarantees, as the case may be.

ARTICLE 6

DEFAULTS AND REMEDIES

Section 6.01 Events of Default.

Each of the following is an “Event of Default” with respect to the Notes of any series:

(a) default for 30 days in the payment when due of interest on such Notes;

(b) default in the payment when due of the principal of, or premium, if any, on such Notes;

(c) failure by the Issuer for 180 days after receipt of written notice given by the Trustee to the Issuer or Holders of at least 30% in aggregate principal amount of the Notes of such series then outstanding voting as a single class to the Issuer and the Trustee, to comply with Section 4.03;

(d) failure by the Issuer or any Guarantor for 60 days after receipt of written notice given by the Trustee to the Issuer or Holders of at least 30% in aggregate principal amount of Notes of such series then outstanding voting as a single class to the Issuer and the Trustee, to comply with any of the agreements in this Indenture other than those described in clauses (a), (b) and (c) of this Section 6.01;

(e) default under any mortgage, indenture or instrument under which there is issued or by which there is secured or evidenced any Indebtedness for money borrowed by the Issuer or any Restricted Subsidiary (other than a Non-Recourse Subsidiary), or the payment of which is guaranteed by the Issuer or any Restricted Subsidiary (other than a Non-Recourse Subsidiary), whether such Indebtedness or guarantee now exists, or is created after the Issue Date, if both:

(1) such default either results from the failure to pay principal on such Indebtedness at its stated final maturity (after giving effect to any applicable grace periods) or relates to an obligation other than the obligation to pay principal of any such Indebtedness at its stated final maturity and results in the holder or holders of such Indebtedness causing such Indebtedness to become due prior to its stated final maturity; and

 

114


(2) the principal amount of any such Indebtedness, together with the principal amount of any other such Indebtedness in default for failure to pay principal at stated final maturity (after giving effect to applicable grace periods), or the maturity of which has been so accelerated, exceeds the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period,

provided that this clause (e) shall not apply to secured Indebtedness that becomes due as a result of the voluntary sale or transfer of the property or assets securing such Indebtedness to a Person that is not an Affiliate of the Issuer;

(f) one or more judgments for the payment of money in an aggregate amount in excess of the greater of (A) $100.0 million and (B) 3.0% of Distributable Cash for the applicable Test Period (excluding therefrom any amount reasonably expected to be covered by insurance) shall be rendered against the Issuer or any Restricted Subsidiary (other than a Non-Recourse Subsidiary) or any combination thereof and the same shall not have been paid, discharged or stayed for a period of 60 days after such judgment became final and non-appealable;

(g) except as permitted by this Indenture, any Guarantee of the Notes of such series shall be held in any final and non-appealable judgment to be unenforceable or invalid or shall cease for any reason to be in full force and effect;

(h) the Issuer or any Guarantor pursuant to or within the meaning of Bankruptcy Law:

(1) commences a voluntary case,

(2) consents to the entry of an order for relief against it in an involuntary case,

(3) consents to the appointment of a custodian of it or for all or substantially all of its property,

(4) makes a general assignment for the benefit of its creditors, or

(5) generally is not paying its debts as they become due;

(i) a court of competent jurisdiction enters an order or decree under any Bankruptcy Law that:

(1) is for relief against the Issuer or any Guarantor in an involuntary case;

(2) appoints a custodian of the Issuer or any Guarantor; or

(3) orders the liquidation of the Issuer or any Guarantor;

and the order or decree remains unstayed and in effect for 60 consecutive days; and

 

115


(j) other than by reason of the satisfaction in full of all obligations under this Indenture and discharge of this Indenture with respect to the Notes of such series or the release of the Collateral with respect to the Notes of such series in accordance with the terms of this Indenture and the Security Documents, (i)(A) in the case of any security interest with respect to any material portion of the Collateral, such security interest under the Security Documents shall, at any time, cease to be a valid and perfected security interest or shall be declared invalid or unenforceable except to the extent that any such perfection or priority is not required pursuant to the Security Documents or this Indenture or the Issuer or the relevant Guarantor, as applicable, has delivered all required certificates representing securities pledged under the Security Documents to the Collateral Agent, or (B) in the case of any security interest with respect to any material portion of the Collateral, the Issuer or any Guarantor shall assert, in any pleading in any court of competent jurisdiction, that any security interest under any Security Document is invalid or unenforceable, and (ii) such default continues for 30 days after receipt of written notice given by the Trustee to the Issuer or the Holders of not less than 30% in aggregate principal amount of the then outstanding Notes of such series to the Issuer and the Trustee.

Section 6.02 Acceleration.

In the case of an Event of Default with respect to the Notes of any series specified in clause (h) or (i) of Section 6.01 hereof with respect to the Issuer, all outstanding Notes of such series will become due and payable immediately without further action or notice. If any other Event of Default occurs and is continuing, the Trustee by written notice to the Issuer or the Holders of at least 30% in aggregate principal amount of the then outstanding Notes of such series by written notice to the Issuer and the Trustee, may declare all the Notes of such series to be due and payable immediately. Upon any such declaration, the Notes of such series shall become due and payable immediately.

The Holders of a majority in aggregate principal amount of the then outstanding Notes of a series by written notice to the Issuer and the Trustee, and the Trustee may, on behalf of the Holders of all the Notes of such series, rescind an acceleration and its consequences hereunder, if the rescission would not conflict with any judgment or decree and if all existing Events of Default (except nonpayment of principal of, premium on, if any, or interest, if any, on the Notes of such series that has become due solely because of the declaration of acceleration) have been cured or waived.

In the event of a declaration of acceleration of the Notes of any series because an Event of Default described in clause (e) of Section 6.01 has occurred and is continuing, the declaration of acceleration of the Notes of such series shall be automatically annulled if the default triggering such Event of Default pursuant to such clause (e) of Section 6.01 shall be remedied or cured, or waived by the holders of the Indebtedness with respect to which such default has occurred within 30 days after the declaration of acceleration of such Notes; provided that (a)(1) the annulment of the acceleration of the Notes of such series would not conflict with any judgment or decree of a court of competent jurisdiction and (2) all existing Events of Default, except nonpayment of principal, premium or interest on the Notes of such series that became due solely because of the acceleration of the Notes of such series, have been cured or waived, (b) the Indebtedness or guarantee that is the basis for such Event of Default has been discharged, or (c) the requisite number of holders thereof have rescinded or waived the acceleration, notice or action (as the case may be) giving rise to such Event of Default.

 

116


If a Default occurs for a failure to report or deliver a required certificate in connection with another default (an “Initial Default”) then at the time such Initial Default is cured, such Default for a failure to report or deliver a required certificate in connection with the Initial Default will also be cured without any further action and any Default or Event of Default for the failure to comply with the time periods prescribed in Section 4.03 or otherwise to deliver any notice or certificate pursuant to any other provision of this Indenture shall be deemed to be cured upon the delivery of any such report required by such covenant or notice or certificate, as applicable, even though such delivery is not within the prescribed period specified in this Indenture.

Any notice of an Event of Default, notice of acceleration or instruction to the Trustee to provide a notice of an Event of Default, notice of acceleration or take any other action in connection with an Event of Default and/or acceleration of the Notes of a series (a “Noteholder Direction”) provided by any one or more holders (each a “Directing Holder”) must be accompanied by a written representation from each such holder of Notes of such series delivered to the Issuer and the Trustee that such holder is not (or, in the case such holder is DTC, or its nominee, that such holder is being instructed solely by beneficial owners that have represented to such holder that they are not) Net Short (a “Position Representation”), which representation, in the case of a Noteholder Direction relating to the delivery of a notice of an Event of Default shall be deemed a continuing representation until the resulting Event of Default is cured or otherwise ceases to exist or such Notes are accelerated. In addition, each Directing Holder is deemed, at the time of providing a Noteholder Direction, to covenant to provide the Issuer with such other information as the Issuer may reasonably request from time to time in order to verify the accuracy of such holder’s Position Representation within five Business Days of request therefor (a “Verification Covenant”). In any case in which the holder is DTC, or its nominee, any Position Representation or Verification Covenant required hereunder shall be provided by the beneficial owner of such Notes in lieu of DTC, or its nominee, and DTC shall be entitled to conclusively rely on such Position Representation and Verification Covenant in delivering its direction to the Trustee.

If, following the delivery of a Noteholder Direction, but prior to acceleration of the Notes of a series, the Issuer determines in good faith that there is a reasonable basis to believe a Directing Holder was, at any relevant time, in breach of its Position Representation and provides to the Trustee an Officer’s Certificate stating that the Issuer has initiated litigation in a court of competent jurisdiction seeking a determination that such Directing Holder was, at such time, in breach of its Position Representation, and seeking to invalidate any Event of Default that resulted from the applicable Noteholder Direction, the cure period with respect to such Event of Default shall be automatically stayed and the cure period with respect to such Event of Default shall be automatically reinstituted and any remedy stayed pending a final and non-appealable determination of a court of competent jurisdiction on such matter (a “Court Determination”). If, following the delivery of a Noteholder Direction, but prior to acceleration of the Notes of such series, the Issuer provides to the Trustee an Officer’s Certificate stating that a Directing Holder failed to satisfy its Verification Covenant, the cure period with respect to such Event of Default shall be automatically stayed and the cure period with respect to any Event of Default that resulted from the applicable Noteholder Direction shall be automatically reinstituted and any remedy stayed pending satisfaction of such Verification Covenant, and confirmation of such satisfaction shall be provided in writing by the Issuer to the Trustee. Any breach of the Position Representation (as confirmed by a Court Determination) shall result in such holder’s participation in such Noteholder Direction being disregarded; and, if, without the participation of such noteholder, the percentage of Notes of such series held by the remaining noteholders that provided such Noteholder Direction would have been insufficient to validly provide such Noteholder Direction,

 

117


such Noteholder Direction shall be void ab initio, with the effect that such Event of Default shall be deemed never to have occurred, acceleration voided and the Trustee shall be deemed not to have received such Noteholder Direction or any notice of such Event of Default; provided, however, that this shall not invalidate any indemnity or security provided by any Directing Holder to the Trustee.

Notwithstanding anything in the preceding two paragraphs to the contrary, any Noteholder Direction delivered to the Trustee during the pendency of an Event of Default as the result of a bankruptcy or similar proceeding shall not require compliance with the foregoing paragraphs. For the avoidance of doubt, the Trustee shall be entitled to conclusively rely on any Noteholder Direction, Position Representation, Verification Covenant, Officer’s Certificate or other document delivered to it in accordance with this Indenture, shall have no duty to monitor, inquire as to or investigate the accuracy of, or compliance with, any Position Representation or any Verification Covenant, verify any statements in any Officer’s Certificate delivered to it, or otherwise make calculations, investigations or determinations or take any other actions with respect to Derivative Instruments, Net Shorts, Long Derivative Instruments, Short Derivative Instruments or otherwise. The Trustee shall have no liability to the Issuer, any holder or any other Person in acting in good faith pursuant to a Noteholder Direction without regard to any Position Representation or compliance with any Verification Covenant, and all such parties agree not to commence any legal proceedings against the Trustee in respect of, and agree that the Trustee will not be liable for, the delivery and accuracy of, or compliance with, any Position Representation or any Verification Covenant.

Section 6.03 Other Remedies.

If an Event of Default occurs and is continuing with respect to the Notes of any series, the Trustee may pursue any available remedy to collect the payment of principal of, premium on, if any, or interest, if any, on the Notes of such series or to enforce the performance of any provision of the Notes of such series or this Indenture.

The Trustee may maintain a proceeding even if it does not possess any of the Notes of a series or does not produce any of them in the proceeding. A delay or omission by the Trustee or any Holder in exercising any right or remedy accruing upon an Event of Default shall not impair the right or remedy or constitute a waiver of or acquiescence in the Event of Default. All remedies are cumulative to the extent permitted by law.

Section 6.04 Waiver of Past Defaults.

The Holders of at least a majority in aggregate principal amount of the then outstanding Notes voting as a class by written notice to the Trustee may, on behalf of the Holders of all of the Notes waive any existing Default or Event of Default and its consequences hereunder, except a continuing Default in the payment of principal of, premium on, if any, or interest, if any, on, any Note held by a non-consenting Holder (including in connection with an offer to purchase); provided, however, that the Holders of a majority in aggregate principal amount of the then outstanding Notes may rescind an acceleration and its consequences, including any related payment default that resulted from such acceleration. If any waiver will only affect one series of Notes (or less than all series of Notes) then outstanding under this Indenture, then only the waiver

 

118


of the holders of a majority in principal amount of the Notes of such series then outstanding (including, in each case, consents obtained in connection with a purchase of, or tender offer or exchange offer for, any such Notes) shall be required and (y) if any such waiver by its terms will affect a series of Notes in a manner different and materially adverse relative to the manner such amendment or waiver affects other series of Notes, then the waiver of the holders of a majority in principal amount of the Notes of such series then outstanding (including, in each case, consents obtained in connection with a purchase of, or tender offer or exchange offer for, any such Notes) shall be required. Upon any such waiver, such Default shall cease to exist, and any Event of Default arising therefrom shall be deemed to have been cured for every purpose of this Indenture; but no such waiver shall extend to any subsequent or other Default or impair any right consequent thereon.

Section 6.05 Control by Majority.

Holders of a majority in aggregate principal amount of the then outstanding Notes of a series may direct the time, method and place of conducting any proceeding for exercising any remedy available to the Trustee or the Collateral Agent or exercising any trust or power conferred on it with respect to such series of Notes. However, the Trustee or the Collateral Agent may refuse to follow any direction that conflicts with law or this Indenture, or that that the Trustee or the Collateral Agent determines may be unduly prejudicial to the rights of other Holders of Notes of such series or that may involve the Trustee or the Collateral Agent in personal liability.

Section 6.06 Limitation on Suits.

Except to enforce the contractual right to receive payment of principal, premium, if any, or interest when due on or after the respective due dates expressed in an outstanding Note, no Holder of a Note may pursue any remedy with respect to this Indenture or the Notes unless:

(a) such Holder has previously given the Trustee written notice that an Event of Default is continuing;

(b) Holders of at least 30% in aggregate principal amount of the then outstanding Notes of the applicable series make a written request to the Trustee to pursue the remedy;

(c) such Holder or Holders offer and, if requested, provide to the Trustee security or indemnity reasonably satisfactory to the Trustee against any loss, liability or expense;

(d) the Trustee has not complies with such request within 60 days after receipt of the request and the offer of security or indemnity; and

(e) during such 60-day period, Holders of a majority in aggregate principal amount of the then outstanding Notes of the applicable series do not give the Trustee a direction inconsistent with such written request within such 60 day period.

A Holder may not use this Indenture to prejudice the rights of another Holder or to obtain a preference or priority over another Holder.

 

119


Section 6.07 Rights of Holders of Notes to Receive Payment.

Notwithstanding any other provision of this Indenture, the right of any Holder to receive payment of principal of, premium on, if any, or interest, if any, on a Note of any series, on or after the respective due dates expressed in such Note (including in connection with an offer to purchase), or to bring suit for the enforcement of any such payment on or after such respective dates, shall not be impaired or affected without the consent of such Holder.

Section 6.08 Collection Suit by Trustee.

If an Event of Default specified in Section 6.01(a) or (b) hereof occurs and is continuing with respect to the Notes of any series, the Trustee is authorized to recover judgment in its own name and as trustee of an express trust against the Issuer for the whole amount of principal of, premium on, if any, and interest, if any, remaining unpaid on the Notes of such series and interest on overdue principal and, to the extent lawful, interest and such further amount as shall be sufficient to cover the costs and expenses of collection, including the reasonable compensation, expenses, disbursements and advances of the Trustee, the Agents and their respective agents and counsel.

If the Trustee or any Holder has instituted any proceeding to enforce any right or remedy under this Indenture and such proceeding has been discontinued or abandoned for any reason, or has been determined adversely to the Trustee or to such Holder, then and in every such case, subject to any determination in such proceedings, the Issuer, the Trustee and the Holders shall be restored severally and respectively to their former positions hereunder and thereafter all rights and remedies of the Trustee and the Holders shall continue as though no such proceeding has been instituted.

Section 6.09 Trustee May File Proofs of Claim.

The Trustee is authorized to file such proofs of claim and other papers or documents as may be necessary or advisable in order to have the claims of the Trustee (including any claim for the reasonable compensation, expenses, disbursements and advances of the Trustee, its agents and counsel) and the Holders allowed in any judicial proceedings relative to the Issuer (or any other obligor upon the Notes), its creditors or its property and shall be entitled and empowered to collect, receive and distribute any money or other property payable or deliverable on any such claims and any custodian in any such judicial proceeding is hereby authorized by each Holder to make such payments to the Trustee, and in the event that the Trustee shall consent to the making of such payments directly to the Holders, to pay to the Trustee any amount due to it for the reasonable compensation, expenses, disbursements and advances of the Trustee, the Agents and their respective agents and counsel, and any other amounts due the Trustee under Section 7.06 hereof. To the extent that the payment of any such compensation, expenses, disbursements and advances of the Trustee, the Agents and their respective agents and counsel, and any other amounts due the Trustee under Section 7.06 hereof out of the estate in any such proceeding, shall be denied for any reason, payment of the same shall be secured by a Lien on, and shall be paid out of, any and all distributions, dividends, money, securities and other properties that the Holders may be entitled to receive in such proceeding whether in liquidation or under any plan of reorganization or arrangement or otherwise. Nothing herein contained shall be deemed to authorize the Trustee to authorize or consent to or accept or adopt on behalf of any Holder any plan of reorganization, arrangement, adjustment or composition affecting the Notes of any series or the rights of any Holder, or to authorize the Trustee to vote in respect of the claim of any Holder in any such proceeding.

 

120


Section 6.10 Priorities.

Subject to any First Lien Intercreditor Agreement, if the Trustee collects any money or property pursuant to this Article 6 or pursuant to the Security Documents, it shall pay out the money or property in the following order:

First: to the Trustee and to the Collateral Agent, in each case, and their respective agents and attorneys for amounts due under Section 7.06 hereof, including payment of all compensation, expenses and liabilities incurred, and all advances made, by the Trustee and the Collateral Agent and the costs and expenses of collection;

Second: to Holders for amounts due and unpaid on the Notes for principal, premium, if any, and interest, if any, ratably, without preference or priority of any kind, according to the amounts due and payable on the Notes for principal, premium, if any, and interest, if any, respectively; and

Third: to the Issuer or to such party as a court of competent jurisdiction shall direct, including a Guarantor, if applicable

The Trustee may fix a record date and payment date for any payment to Holders of Notes of any series pursuant to this Section 6.10.

Section 6.11 Undertaking for Costs.

In any suit for the enforcement of any right or remedy under this Indenture or in any suit against the Trustee for any action taken or omitted by it as a Trustee, a court in its discretion may require the filing by any party litigant in the suit of an undertaking to pay the costs of the suit, and the court in its discretion may assess reasonable costs, including reasonable attorneys’ fees, against any party litigant in the suit, having due regard to the merits and good faith of the claims or defenses made by the party litigant. This Section 6.11 does not apply to a suit by the Trustee, a suit by a Holder pursuant to Section 6.07 hereof, or a suit by Holders of more than 10% in aggregate principal amount of the then outstanding Notes of a series.

ARTICLE 7

TRUSTEE

Section 7.01 Duties of Trustee.

(a) If an Event of Default has occurred and is continuing, the Trustee will exercise such of the rights and powers vested in it by this Indenture, and use the same degree of care and skill in its exercise, as a prudent person would exercise or use under the circumstances in the conduct of such person’s own affairs.

 

121


(b) Except during the continuance of an Event of Default:

(1) the duties of the Trustee will be determined solely by the express provisions of this Indenture and the Trustee need perform only those duties that are specifically set forth in this Indenture and no others, and no implied covenants or obligations shall be read into this Indenture against the Trustee; and

(2) in the absence of bad faith on its part, the Trustee may conclusively rely, as to the truth of the statements and the correctness of the opinions expressed therein, upon certificates or opinions furnished to the Trustee and conforming to the requirements of this Indenture. However, the Trustee will examine the certificates and opinions to determine whether or not they conform to the requirements of this Indenture.

(c) The Trustee may not be relieved from liabilities for its own negligent action, its own negligent failure to act, or its own willful misconduct, except that:

(1) this paragraph does not limit the effect of paragraph (b) of this Section 7.01;

(2) the Trustee will not be liable for any error of judgment made in good faith by a Responsible Officer, unless it is proved that the Trustee was negligent in ascertaining the pertinent facts; and

(3) the Trustee will not be liable with respect to any action it takes or omits to take in good faith in accordance with a direction received by it pursuant to Section 6.05 hereof.

(d) Whether or not therein expressly so provided, every provision of this Indenture that in any way relates to the Trustee is subject to this Section 7.01.

(e) No provision of this Indenture will require the Trustee to expend or risk its own funds or incur any liability. The Trustee will be under no obligation to exercise any of its rights or powers under this Indenture at the request of any Holders, unless such Holder has offered to the Trustee security and indemnity satisfactory to it against any loss, liability or expense.

(f) The Trustee will not be liable for interest on any money received by it except as the Trustee may agree in writing with the Issuer. Money held in trust by the Trustee need not be segregated from other funds except to the extent required by law.

Section 7.02 Rights of Trustee.

(a) The Trustee may conclusively rely upon any document believed by it to be genuine and to have been signed or presented by the proper Person. The Trustee need not investigate any fact or matter stated in the document.

(b) Before the Trustee acts or refrains from acting, it may require an Officer’s Certificate or an Opinion of Counsel or both. The Trustee will not be liable for any action it takes or omits to take in good faith in reliance on such Officer’s Certificate or Opinion of Counsel. The Trustee may consult with counsel and the written advice of such counsel or any Opinion of Counsel will be full and complete authorization and protection from liability in respect of any action taken, suffered or omitted by it hereunder in good faith and in reliance thereon.

 

122


(c) The Trustee may act through its attorneys and agents and will not be responsible for the misconduct or negligence of any agent appointed with due care.

(d) The Trustee will not be liable for any action it takes or omits to take in good faith that it believes to be authorized or within the rights or powers conferred upon it by this Indenture.

(e) Unless otherwise specifically provided in this Indenture, any demand, request, direction or notice from the Issuer will be sufficient if signed by an Officer of the Issuer.

(f) The Trustee will be under no obligation to exercise any of the rights or powers vested in it by this Indenture at the request or direction of any of the Holders unless such Holders have offered to the Trustee indemnity or security satisfactory to the Trustee against the losses, liabilities and expenses that might be incurred by it in compliance with such request or direction.

(g) The Trustee shall not be deemed to have notice of any Default hereunder or Event of Default unless a Responsible Officer of the Trustee has actual knowledge thereof or unless written notice of any event which is in fact such a Default or Event of Default is received by a Responsible Officer at the Corporate Trust Office of the Trustee, and such notice references the Notes and this Indenture.

(h) The rights, privileges, protections, immunities and benefits given to the Trustee, including, without limitation, its right to be indemnified, are extended to, and shall be enforceable by, the Trustee in each of its capacities hereunder.

(i) In no event shall the Trustee be responsible or liable for special, punitive, indirect, or consequential loss or damage of any kind whatsoever (including, but not limited to, loss of profit) irrespective of whether the Trustee has been advised of the likelihood of such loss or damage and regardless of the form of action.

(j) The Trustee may request that the Issuer deliver an Officer’s Certificate setting forth the names of individuals and/or titles of officers authorized at such time to take specified actions pursuant to this Indenture, which Officer’s Certificate may be signed by any person authorized to sign an Officer’s Certificate, including any person specified as so authorized in any such certificate previously delivered and not superseded.

(k) In no event shall the Trustee be responsible or liable for any failure or delay in the performance of its obligations hereunder arising out of or caused by, directly or indirectly, forces beyond its control, including, without limitation, strikes, work stoppages, accidents, acts of war or terrorism, civil or military disturbances, nuclear or natural catastrophes or acts of God, and interruptions, loss or malfunctions of utilities, communications or computer (software and hardware) services; it being understood that the Trustee shall use reasonable efforts which are consistent with accepted practices in the banking industry to resume performance as soon as practicable under the circumstances.

(l) The parties hereto acknowledge that in accordance with Section 326 of the U.S.A. PATRIOT Act, the Trustee, like all financial institutions and in order to help fight the funding of terrorism and money laundering, is required to obtain, verify, and record information that identifies each person or legal entity that establishes a relationship or opens an account with the Trustee. The parties to this Indenture agree that they will provide the Trustee with such information as it may request in order for the Trustee to satisfy the requirements of the U.S.A. PATRIOT Act.

 

 

123


(m) The Trustee shall have the right to accept and act upon instructions, including funds transfer instructions (“Instructions”) given pursuant to this Indenture and any other Transaction Document and delivered using Electronic Means; provided, however, that the Issuer and the Guarantors shall provide to the Trustee an incumbency certificate listing officers with the authority to provide such Instructions (“Instructing Officers”) and containing specimen signatures of such Instructing Officers, which incumbency certificate shall be amended by the Issuer and/or the Guarantors, as applicable, whenever a person is to be added or deleted from the listing. If the Issuer and/or the Guarantors, as applicable, elects to give the Trustee Instructions using Electronic Means and the Trustee in its discretion elects to act upon such Instructions, the Trustee’s understanding of such Instructions shall be deemed controlling. The Issuer and the Guarantors understand and agree that the Trustee cannot determine the identity of the actual sender of such Instructions and that the Trustee shall conclusively presume that directions that purport to have been sent by an Instructing Officer listed on the incumbency certificate provided to the Trustee have been sent by such Instructing Officer. The Issuer and the Guarantors shall be responsible for ensuring that only Instructing Officers transmit such Instructions to the Trustee and that the Issuer, the Guarantors and all Instructing Officers are solely responsible to safeguard the use and confidentiality of applicable user and authorization codes, passwords and/or authentication keys upon receipt by the Issuer and/or the Guarantors, as applicable. The Trustee shall not be liable for any losses, costs or expenses arising directly or indirectly from the Trustee’s reliance upon and compliance with such Instructions notwithstanding such directions conflict or are inconsistent with a subsequent written instruction. The Issuer and the Guarantors agree: (i) to assume all risks arising out of the use of Electronic Means to submit Instructions to the Trustee, including without limitation the risk of the Trustee acting on unauthorized Instructions, and the risk of interception and misuse by third parties; (ii) that it is fully informed of the protections and risks associated with the various methods of transmitting Instructions to the Trustee and that there may be more secure methods of transmitting Instructions than the method(s) selected by the Issuer and/or the Guarantors, as applicable; (iii) that the security procedures (if any) to be followed in connection with its transmission of Instructions provide to it a commercially reasonable degree of protection in light of its particular needs and circumstances; and (iv) to notify the Trustee immediately upon learning of any compromise or unauthorized use of the security procedures.

Section 7.03 Individual Rights of Trustee.

The Trustee in its individual or any other capacity may become the owner or pledgee of Notes and may otherwise deal with the Issuer or any Affiliate of the Issuer with the same rights it would have if it were not Trustee. However, in the event that the Trustee acquires any conflicting interest it must eliminate such conflict within 90 days or resign. Any Agent may do the same with like rights and duties. The Trustee is also subject to Section 7.09 hereof

Section 7.04 Trustees Disclaimer.

The Trustee will not be responsible for and makes no representation as to the validity or adequacy of this Indenture or the Notes, it shall not be accountable for the Issuer’s use of the proceeds from the Notes or any money paid to the Issuer or upon the Issuer’s direction under any provision of this Indenture, it will not be responsible for the use or application of any money received by any Paying Agent other than the Trustee, and it will not be responsible for any statement or recital herein or any statement in the Notes or any other document in connection with the sale of the Notes or pursuant to this Indenture other than its certificate of authentication.

 

124


Section 7.05 Notice of Defaults.

If a Default or Event of Default occurs and is continuing and if it is known to a Responsible Officer of the Trustee as described in Section 7.02(g), the Trustee will deliver (or, in the case of Global Notes, transmit pursuant to the Applicable Procedures) to Holders of Notes a notice of the Default or Event of Default within 90 days after it occurs, unless such Default shall have been cured or waived, or if discovered after 90 days, promptly thereafter. Except in the case of a Default or Event of Default in payment of principal of, premium on, if any, interest, if any, on, any Note, the Trustee may withhold the notice if and so long as a committee of its Responsible Officers in good faith determines that withholding the notice is in the interests of the Holders.

Section 7.06 Compensation and Indemnity.

(a) The Issuer will pay to the Trustee from time to time reasonable compensation for its acceptance of this Indenture and services hereunder as agreed in writing between the Issuer and the Trustee. The Trustee’s compensation will not be limited by any law on compensation of a trustee of an express trust. The Issuer will reimburse the Trustee promptly upon request for all reasonable disbursements, advances and expenses incurred or made by it in addition to the compensation for its services. Such expenses will include the reasonable compensation, disbursements and expenses of the Trustee’s agents and counsel.

(b) The Issuer and the Guarantors will, jointly and severally, indemnify the Trustee against any and all losses, liabilities or expenses incurred by it arising out of or in connection with the acceptance or administration of its duties under this Indenture, including the costs and expenses of enforcing this Indenture against the Issuer and the Guarantors (including this Section 7.06) and defending itself against any claim (whether asserted by the Issuer, the Guarantors, any Holder or any other Person) or liability in connection with the exercise or performance of any of its powers or duties hereunder, except to the extent any such loss, liability or expense may be attributable to its own gross negligence or willful misconduct, as determined by a final, non-appealable decision of a court of competent jurisdiction. The Trustee will notify the Issuer promptly of any claim for which it may seek indemnity. Failure by the Trustee to so notify the Issuer will not relieve the Issuer or any of the Guarantors of their obligations hereunder. Neither the Issuer nor any Guarantor need pay for any settlement made without its consent, which consent will not be unreasonably withheld, conditioned or delayed.

(c) The obligations of the Issuer and the Guarantors under this Section 7.06 will survive the satisfaction and discharge of this Indenture.

(d) To secure the Issuer’s and the Guarantors’ payment obligations in this Section 7.06, the Trustee will have a Lien prior to the Notes on all money or property held or collected by the Trustee, except that held in trust to pay principal of, premium on, if any, interest, if any, on, particular Notes. Such Lien will survive the satisfaction and discharge of this Indenture.

 

125


(e) When the Trustee incurs expenses or renders services after an Event of Default specified in clause (h) or (i) of Section 6.01 hereof occurs, the expenses and the compensation for the services (including the fees and expenses of its agents and counsel) are intended to constitute expenses of administration under any Bankruptcy Law.

Section 7.07 Replacement of Trustee.

(a) A resignation or removal of the Trustee and appointment of a successor Trustee will become effective only upon the successor Trustee’s acceptance of appointment as provided in this Section 7.07.

(b) The Trustee may resign in writing at any time and be discharged from the trust hereby created by so notifying the Issuer. The Holders of a majority in aggregate principal amount of the then outstanding Notes may remove the Trustee by so notifying the Trustee and the Issuer in writing. The Issuer may remove the Trustee if:

(1) the Trustee fails to comply with Section 7.09 hereof;

(2) the Trustee is adjudged a bankrupt or an insolvent or an order for relief is entered with respect to the Trustee under any Bankruptcy Law;

(3) a custodian or public officer takes charge of the Trustee or its property; or

(4) the Trustee becomes incapable of acting.

(c) If the Trustee resigns or is removed or if a vacancy exists in the office of Trustee for any reason, the Issuer will promptly appoint a successor Trustee. Within one year after the successor Trustee takes office, the Holders of a majority in aggregate principal amount of the then outstanding Notes may appoint a successor Trustee to replace the successor Trustee appointed by the Issuer.

(d) If a successor Trustee does not take office within 60 days after the retiring Trustee resigns or is removed, the retiring Trustee, the Issuer, or the Holders of at least 10% in aggregate principal amount of the then outstanding Notes may petition any court of competent jurisdiction for the appointment of a successor Trustee.

(e) If the Trustee, after written request by any Holder who has been a Holder for at least six months, fails to comply with Section 7.09 hereof, such Holder may petition any court of competent jurisdiction for the removal of the Trustee and the appointment of a successor Trustee.

(f) A successor Trustee will deliver a written acceptance of its appointment to the retiring Trustee and to the Issuer. Thereupon, the resignation or removal of the retiring Trustee will become effective, and the successor Trustee will have all the rights, powers and duties of the Trustee under this Indenture. The successor Trustee will mail a notice of its succession to Holders. The retiring Trustee will promptly transfer all property held by it as Trustee to the successor Trustee; provided all sums owing to the Trustee hereunder have been paid and subject to the Lien provided for in Section 7.06 hereof Notwithstanding replacement of the Trustee pursuant to this Section 7.07, the Issuer’s obligations under Section 7.06 hereof will continue for the benefit of the retiring Trustee.

 

126


Section 7.08 Successor Trustee by Merger, etc.

If the Trustee consolidates, merges or converts into, or transfers all or substantially all of its corporate trust business to, another corporation, the successor corporation without any further act will be the successor Trustee.

Section 7.09 Eligibility; Disqualification.

There will at all times be a Trustee hereunder that is a corporation organized and doing business under the laws of the United States of America or of any state thereof that is authorized under such laws to exercise corporate trust powers, that is subject to supervision or examination by federal or state authorities and that has a combined capital and surplus of at least $100.0 million as set forth in its most recent published annual report of condition.

Section 7.10 Security Documents.

By their acceptance of the Notes, the Holders hereby authorize and direct the Trustee and the Collateral Agent to execute and deliver this Indenture, the Security Documents in which the Trustee or the Collateral Agent is named as a party, including any Security Documents executed on or after the Issue Date. It is hereby expressly acknowledged and agreed that, in doing so, the Trustee and the Collateral Agent are not responsible for the terms or contents of such agreements, or for the validity or enforceability thereof, or the sufficiency thereof for any purpose. Whether or not so expressly stated therein, in entering into, or taking (or forbearing from) any action under, this Indenture, the Security Documents, the Trustee and the Collateral Agent each shall have all of the rights, privileges, benefits, immunities, indemnities and other protections granted to it under this Indenture (in the case of the Trustee) and the Collateral Agency Agreement (in the case of the Collateral Agent) (in addition to those that may be granted to it under the terms of such other agreement or agreements).

ARTICLE 8

LEGAL DEFEASANCE AND COVENANT DEFEASANCE

Section 8.01 Option to Effect Legal Defeasance or Covenant Defeasance.

The Issuer may, at the option of its Board of Directors evidenced by a resolution set forth in an Officer’s Certificate, at any time, elect to have either Section 8.02 or 8.03 hereof be applied to all outstanding Notes of a series upon compliance with the conditions set forth below in this Article 8.

 

127


Section 8.02 Legal Defeasance and Discharge.

Upon the Issuer’s exercise under Section 8.01 hereof of the option applicable to this Section 8.02, the Issuer and each of the Guarantors will, subject to the satisfaction of the conditions set forth in Section 8.04 hereof, be deemed to have been discharged from their obligations with respect to all outstanding Notes of any series (including any Guarantees of such Notes) on the date the conditions set forth below are satisfied (hereinafter, “Legal Defeasance”). For this purpose, Legal Defeasance means that the Issuer and the Guarantors will be deemed to have paid and discharged the entire Indebtedness represented by the outstanding Notes of the applicable series (including any Guarantees of such Notes and the Security Documents with respect to such Notes and all Defaults and Events of Default cured), which will thereafter be deemed to be “outstanding” only for the purposes of Section 8.05 hereof and the other Sections of this Indenture referred to in clauses (a) and (b) below, and to have satisfied all their other obligations under such Notes, any Guarantees of such Notes the applicable Security Documents and this Indenture (and the Trustee, on demand of and at the expense of the Issuer, shall execute proper instruments acknowledging the same) and to have cured all then existing Defaults and Events of Default, except for the following provisions which will survive until otherwise terminated or discharged hereunder:

(a) the rights of Holders of outstanding Notes of such series to receive payments in respect of the principal of, premium on, if any, or interest, if any, on such Notes when such payments are due from the trust created pursuant to this Indenture referred to in Section 8.04 hereof;

(b) the Issuer’s obligations with respect to the Notes of such series under Article 2 and Section 4.02 hereof;

(c) the rights, powers, trusts, duties and immunities of the Trustee hereunder and the Issuer’s and the Guarantors’ obligations in connection therewith; and

(d) this Article 8.

Subject to compliance with this Article 8, the Issuer may exercise its option under this Section 8.02 notwithstanding the prior exercise of its option under Section 8.03 hereof.

Section 8.03 Covenant Defeasance.

Upon the Issuer’s exercise under Section 8.01 hereof of the option applicable to this Section 8.03 with respect to any series of Notes, the Issuer and each of the Guarantors will, subject to the satisfaction of the conditions set forth in Section 8.04 hereof, be released from each of their obligations under the covenants contained in Sections 3.09, 4.03, 4.04, 4.07, 4.08, 4.09, 4.10, 4.11, 4.12, 4.13, 4.15, 4.16 and 4.17 and clause (4) of Section 5.01 hereof with respect to the outstanding Notes of such series on and after the date the conditions set forth in Section 8.04 hereof are satisfied (hereinafter, “Covenant Defeasance”), and the Notes of such series will thereafter be deemed not “outstanding” for the purposes of any direction, waiver, consent or declaration or act of Holders (and the consequences of any thereof) in connection with such covenants, but will continue to be deemed “outstanding” for all other purposes hereunder (it being understood that such Notes will not be deemed outstanding for accounting purposes). For this purpose, Covenant Defeasance means that, with respect to the outstanding Notes of such series and any Guarantees of such Notes, the Issuer and the Guarantors may omit to comply with and will have no liability in respect of any term, condition or limitation set forth in any such covenant, whether directly or indirectly, by reason of any reference elsewhere herein to any such covenant or by reason of any reference in any such covenant to any other provision herein or in any other document and such omission to

 

128


comply will not constitute a Default or an Event of Default under Section 6.01 hereof with respect to the applicable series of Notes, but, except as specified above, the remainder of this Indenture and such Notes and any Guarantees of such Notes will be unaffected thereby. In addition, upon the Issuer’s exercise under Section 8.01 hereof of the option applicable to this Section 8.03, subject to the satisfaction of the conditions set forth in Section 8.04 hereof, Sections 6.01(c), (d), (e), (f), (g) and (j) hereof will not constitute Events of Default with respect to the Notes of the applicable series.

Section 8.04 Conditions to Legal or Covenant Defeasance.

In order to exercise either Legal Defeasance or Covenant Defeasance under either Section 8.02 or 8.03 hereof:

(a) the Issuer must irrevocably deposit with the Trustee, in trust, for the benefit of the Holders of the applicable series of Notes, cash in U.S. dollars, non-callable Government Securities, or a combination thereof, in such amounts as will be sufficient, in the opinion of a nationally recognized investment bank, appraisal firm, or firm of independent public accountants, to pay the principal of, or interest and premium, if any, on the outstanding Notes of such series on the Stated Maturity or on the applicable redemption date, as the case may be, and the Issuer must specify whether the Notes of such series are being defeased to such Stated Maturity or to a particular redemption date;

(b) in the case of an election under Section 8.02 hereof, the Issuer shall deliver to the Trustee an Opinion of Counsel confirming that:

(1) the Issuer has received from, or there has been published by, the Internal Revenue Service a ruling; or

(2) since the Issue Date, there has been a change in the applicable federal income tax law,

in either case to the effect that, and based thereon such Opinion of Counsel shall confirm that, subject to customary assumptions and exclusions, the Holders of the outstanding Notes of such series will not recognize income, gain or loss for federal income tax purposes as a result of such Legal Defeasance and will be subject to federal income tax on the same amounts, in the same manner and at the same times as would have been the case if such Legal Defeasance had not occurred;

(c) in the case of an election under Section 8.03 hereof, the Issuer shall deliver to the Trustee an Opinion of Counsel confirming that, subject to customary assumptions and exclusions, the Holders of the outstanding Notes of such series will not recognize income, gain or loss for federal income tax purposes as a result of such Covenant Defeasance and will be subject to federal income tax on the same amounts, in the same manner and at the same times as would have been the case if such Covenant Defeasance had not occurred;

(d) no Event of Default with respect to the Notes of the applicable series shall have occurred and is continuing on the date of such deposit (other than an Event of Default resulting from the borrowing of funds to be applied to such deposit (and any similar and simultaneous deposit relating to other Indebtedness), and, in each case, the granting of Liens to secure such borrowings);

 

129


(e) such Legal Defeasance or Covenant Defeasance will not result in a breach or violation of, or constitute a default under, any material agreement or instrument (other than this Indenture and the agreements governing any other Indebtedness being defeased, discharged or replaced) to which the Issuer or any of its Subsidiaries is a party or by which the Issuer or any of its Subsidiaries is bound (other than an Event of Default resulting from the borrowing of funds to be applied to such deposit (and any similar and simultaneous deposit relating to other Indebtedness), and, in each case, the granting of Liens to secure such borrowings);

(f) the Issuer must deliver to the Trustee an Officer’s Certificate stating that the deposit was not made by the Issuer with the intent of preferring the Holders of Notes of the applicable series over the other creditors of the Issuer with the intent of defeating, hindering, delaying or defrauding any creditors of the Issuer or others; and

(g) the Issuer must deliver to the Trustee an Officer’s Certificate and an Opinion of Counsel, which Opinion of Counsel may be subject to customary assumptions and exclusions, each stating that all conditions precedent relating to the Legal Defeasance or the Covenant Defeasance have been complied with.

Section 8.05 Deposited Money and Government Securities to be Held in Trust; Other Miscellaneous Provisions.

Subject to Section 8.06 hereof, all money and non-callable Government Securities (including the proceeds thereof) deposited with the Trustee (or other qualifying trustee, collectively for purposes of this Section 8.05, the “Trustee”) pursuant to Section 8.04 hereof in respect of the outstanding Notes of any series will be held in trust and applied by the Trustee, in accordance with the provisions of such Notes of such series and this Indenture, to the payment, either directly or through any Paying Agent (including the Issuer acting as Paying Agent) as the Trustee may determine, to the Holders of such Notes of all sums due and to become due thereon in respect of principal, premium, if any, and interest, if any, but such money need not be segregated from other funds except to the extent required by law.

The Issuer will pay and indemnify the Trustee against any tax, fee or other charge imposed on or assessed against the cash or non-callable Government Securities deposited pursuant to Section 8.04 hereof or the principal and interest received in respect thereof other than any such tax, fee or other charge which by law is for the account of the Holders of the outstanding Notes of the applicable series.

Notwithstanding anything in this Article 8 to the contrary, the Trustee will deliver or pay to the Issuer from time to time upon the request of the Issuer any money or non-callable Government Securities held by it as provided in Section 8.04 hereof which, in the opinion of a nationally recognized firm of independent public accountants expressed in a written certification thereof delivered to the Trustee (which may be the opinion delivered under Section 8.04(a) hereof), are in excess of the amount thereof that would then be required to be deposited to effect an equivalent Legal Defeasance or Covenant Defeasance.

 

130


Section 8.06 Repayment to Issuer.

Any money deposited with the Trustee or any Paying Agent, or then held by the Issuer, in trust for the payment of the principal of, premium on, if any, or interest, if any, on any Note of a series and remaining unclaimed for two years after such principal, premium, if any, or interest, if any, has become due and payable shall be paid to the Issuer on its request or (if then held by the Issuer) will be discharged from such trust; and the Holder of such Note will thereafter be permitted to look only to the Issuer for payment thereof, and all liability of the Trustee or such Paying Agent with respect to such trust money, and all liability of the Issuer as trustee thereof, will thereupon cease; provided, however, that the Trustee or such Paying Agent, before being required to make any such repayment, may at the expense of the Issuer cause to be published once, in the New York Times and The Wall Street Journal (national edition), notice that such money remains unclaimed and that, after a date specified therein, which will not be less than 30 days from the date of such notification or publication, any unclaimed balance of such money then remaining will be repaid to the Issuer.

Section 8.07 Reinstatement.

If the Trustee or Paying Agent is unable to apply any U.S. dollars or non-callable Government Securities in accordance with Section 8.02 or 8.03 hereof, as the case may be, by reason of any order or judgment of any court or Governmental Authority enjoining, restraining or otherwise prohibiting such application, then the Issuer’s and the Guarantors’ obligations under this Indenture and the Notes of the applicable series and any Guarantees of such Notes will be revived and reinstated as though no deposit had occurred pursuant to Section 8.02 or 8.03 hereof until such time as the Trustee or Paying Agent is permitted to apply all such money in accordance with Section 8.02 or 8.03 hereof, as the case may be; provided, however, that, if the Issuer makes any payment of principal of, premium on, if any, interest, if any, on, any Note of such series following the reinstatement of its obligations, the Issuer will be subrogated to the rights of the Holders of such Notes to receive such payment from the money held by the Trustee or Paying Agent.

ARTICLE 9

AMENDMENT, SUPPLEMENT AND WAIVER

Section 9.01 Without Consent of Holders of Notes.

Notwithstanding Section 9.02 of this Indenture, without the consent of any Holder, the Issuer, the Guarantors, the Trustee and the Collateral Agent may amend or supplement this Indenture, the Notes, any Guarantee or any Security Document:

(a) to cure any ambiguity, mistake defect or inconsistency;

(b) to provide for uncertificated Notes in addition to or in place of certificated Notes;

(c) to provide for the assumption of the Issuer’s obligations to holders of Notes in the case of a merger or consolidation or sale of all or substantially all of the Issuer’s assets;

 

131


(d) to make any change that would provide any additional rights or benefits to the Holders or that does not adversely affect in any material respect the legal rights hereunder of any Holder;

(e) to comply with requirements of the Commission in connection with the qualification of this Indenture under the TIA to the extent this Indenture is to be so qualified;

(f) to add or modify covenants for the benefit of the Holders or to surrender any right or power conferred upon the Issuer or any Guarantor;

(g) to add a co-issuer or a Guarantor under this Indenture;

(h) to comply with the rules of any applicable securities depositary;

(i) to conform the text of this Indenture, the Notes, any Guarantee or any Security Document to any provision of the “Description of Notes” section of the Offering Memorandum, as set forth in an Officer’s Certificate to that effect;

(j) to evidence and provide for the acceptance and appointment under this Indenture or any Security Document of a successor Trustee, Collateral Agent or paying agent pursuant to the requirements hereof or thereof;

(k) to provide for or confirm the issuance of Additional Notes in accordance with this Indenture;

(l) to provide for any Guarantee with respect to the Notes or to effect the release of a Guarantor from any of its obligations under its Guarantee, this Indenture or the Security Documents to the extent permitted hereby or thereby;

(m) to provide for the issuance of exchange notes;

(n) to add customary provisions allowing for the issuance of new notes into escrow;

(o) to enter into any Applicable Intercreditor Agreement;

(p) to confirm or complete the grant of, secure, or expand the Collateral securing, or to add additional assets as Collateral to secure, the Notes and Guarantees;

(q) to confirm and evidence the release, termination or discharge of any Lien or security interest on the Collateral securing the Notes when permitted or required by this Indenture, or the Security Documents;

(r) in the case of any Security Document, to include therein any legend required to be set forth therein pursuant to any Applicable Intercreditor Agreements or to modify any such legend as required by any Applicable Intercreditor Agreements;

(s) to provide for the succession of any parties to the Security Documents (and other amendments that are administrative or ministerial in nature);

 

132


(t) in the case of the Collateral Agency Agreement, in order to subject the security interests in the Collateral in respect of any Additional First Lien Obligations to the terms of the Collateral Agency Agreement, in each case to the extent the incurrence of such Indebtedness, and the grant of all Liens on the Collateral held for the benefit of such Indebtedness were not prohibited under this Indenture; or

(u) with respect to any Security Document, to the extent such amendment is reasonably necessary to comply with the terms of the Collateral Agency Agreement.

Upon the request of the Issuer, and upon receipt by the Trustee and the Collateral Agent of the documents described in Sections 7.02 and 9.05 hereof (as applicable), the Trustee and the Collateral Agent will join with the Issuer (and, with respect to an amended or supplemental indenture for the addition of a new Guarantor pursuant to this Indenture, such new Guarantor) in the execution of any amended or supplemental indenture authorized or permitted by the terms of this Indenture and to make any further appropriate agreements and stipulations that may be therein contained, but neither the Trustee nor the Collateral Agent will be obligated to enter into such amended or supplemental indenture that affects its own rights, duties or immunities under this Indenture or otherwise.

Section 9.02 With Consent of Holders of Notes.

Except as provided below in this Section 9.02, the Issuer, the Guarantors, the Trustee and the Collateral Agent may amend or supplement this Indenture (including, without limitation, Section 3.09, 4.10 and 4.15 hereof) and the Notes, any Guarantee or the Security Documents with the consent of the Holders of at least a majority in aggregate principal amount of the then outstanding Notes (including, without limitation, Additional Notes, if any) voting as a single class (including, without limitation, consents obtained in connection with a tender offer or exchange offer for, or purchase of, any Notes), and, subject to Sections 6.04 and 6.07 hereof, any existing Default (other than a Default on the payment of the principal of, premium on, if any, or interest, if any, on, the Notes, except a payment default resulting from an acceleration that has been rescinded) or compliance with any provision of this Indenture, the Notes any Guarantees, the Security Documents or any Applicable Intercreditor Agreement may be waived with the consent of the Holders of a majority in aggregate principal amount of the then outstanding Notes (including, without limitation, Additional Notes, if any) voting as a single class (including, without limitation, consents obtained in connection with a tender offer or exchange offer for, or purchase of, any Notes), provided that (x) if any such amendment or waiver will only affect one series of Notes (or less than all series of Notes) then outstanding under this Indenture, then only the consent of the holders of a majority in principal amount of the Notes of such series then outstanding (including, in each case, consents obtained in connection with a purchase of, or tender offer or exchange offer for, any such Notes) shall be required and (y) if any such amendment or waiver by its terms will affect a series of Notes in a manner different and materially adverse relative to the manner such amendment or waiver affects other series of Notes, then the consent of the holders of a majority in principal amount of the Notes of each such series then outstanding (including, in each case, consents obtained in connection with a purchase of, or tender offer or exchange offer for, any such Notes) shall be required. Section 2.08 hereof shall determine which Notes are considered to be “outstanding” for purposes of this Section 9.02.

 

133


Upon the request of the Issuer accompanied by a resolution of its Board of Directors authorizing the execution of any such amended or supplemental indenture, and upon the filing with the Trustee and the Collateral Agent of evidence satisfactory to each of the Trustee and the Collateral Agent of the consent of the Holders of Notes as aforesaid, and upon receipt by the Trustee and the Collateral Agent of the documents described in Sections 7.02 and 9.05 hereof (as applicable), the Trustee and the Collateral Agent will join with the Issuer and solely to the extent applicable, the Guarantors, in the execution of such amended or supplemental indenture unless such amended or supplemental indenture directly affects the Trustee’s or the Collateral Agent’s own rights, duties or immunities under this Indenture or otherwise, in which case the Trustee or the Collateral Agent may in its discretion, but will not be obligated to, enter into such amended or supplemental Indenture.

It is not necessary for the consent of the Holders of Notes under this Section 9.02 to approve the particular form of any proposed amendment, supplement or waiver, but it is sufficient if such consent approves the substance thereof.

After an amendment, supplement or waiver under this Section 9.02 becomes effective, the Issuer will transmit in accordance with the Applicable Procedures to the Holders of Notes affected thereby a notice briefly describing the amendment, supplement or waiver. Any failure of the Issuer to mail or transmit such notice, or any defect therein, will not, however, in any way impair or affect the validity of any such amended or supplemental indenture or waiver. Subject to Section 6.04 hereof, the Holders of a majority in aggregate principal amount of the Notes of any series then outstanding voting as a single class may waive compliance in a particular instance by the Issuer with any provision of this Indenture, the Notes, the Guarantees or the Security Documents with respect to such series of Notes. However, without the consent of each affected Holder, an amendment, supplement or waiver under this Section 9.02 may not (with respect to any Notes held by a non-consenting Holder):

(a) reduce the principal amount of Notes whose Holders must consent to an amendment, supplement or waiver;

(b) reduce the principal of or change the stated final maturity of any such Note or alter or waive the provisions with respect to the redemption of such Notes (other than provisions relating to (a) notice periods for redemption and conditions to redemption and (b) as provided above with respect to Sections 3.09, 4.10 and 4.15 hereof);

(c) reduce the rate of or change the time for payment of interest on any such Note;

(d) waive a Default or Event of Default in the payment of principal of, premium on, if any, or interest, if any, on, such Notes (except a rescission of acceleration of such Notes by the Holders of at least a majority in aggregate principal amount of the then outstanding Notes and a waiver of the payment default that resulted from such acceleration);

(e) make any such Note payable in currency other than that stated in such Notes;

(f) make any change in the provisions of this Indenture relating to waivers of past Defaults or the rights of Holders of such Notes to receive payments of principal of, premium, if any, on, or interest, if any, on such Notes; or

 

134


(g) make any change in the preceding amendment and waiver provisions.

Furthermore, without the consent of the Holders of at least two-thirds in aggregate principal amount of the Notes then outstanding voting as one class, an amendment or waiver may not (A) make any change in any Security Document or the provisions in this Indenture relating to the Collateral or the Security Documents or the application of trust proceeds of the Collateral in any case that would release all or substantially all of the Collateral from the Liens of the Security Documents, or (B) change or alter the priority of the Liens securing Obligations in respect of the Notes in any way materially adverse, taken as a whole, to the holders of the Notes, in each case except as permitted by the terms of this Indenture or the Security Documents.

For the avoidance of doubt, no amendment to, or deletion of any of the covenants set forth in Article 4 or action taken in compliance with the covenants in effect at the time of such action, shall be deemed to impair or affect any legal rights of any Holders to receive payment of principal of or premium, if any, or interest on the Notes or to institute suit for the enforcement of any payment on or with respect to such Holder’s Notes.

Section 9.03 Revocation and Effect of Consents.

Until an amendment, supplement or waiver becomes effective, a consent to it by a Holder is a continuing consent by the Holder and every subsequent Holder of a Note or portion of a Note that evidences the same debt as the consenting Holder’s Note, even if notation of the consent is not made on any Note. However, any such Holder or subsequent Holder may revoke the consent as to its Note if the Trustee receives written notice of revocation before the date the amendment, supplement or waiver becomes effective. An amendment, supplement or waiver becomes effective in accordance with its terms and thereafter binds every Holder.

Section 9.04 Notation on or Exchange of Notes.

The Trustee may place an appropriate notation about an amendment, supplement or waiver on any Note thereafter authenticated. The Issuer in exchange for all Notes may issue and the Trustee shall, upon receipt of an Authentication Order, authenticate new Notes that reflect the amendment, supplement or waiver.

Failure to make the appropriate notation or issue a new Note will not affect the validity and effect of such amendment, supplement or waiver.

Section 9.05 Trustee to Sign Amendments, etc.

The Trustee and the Collateral Agent shall sign any amendment, supplement or waiver authorized pursuant to this Article 9 if the amendment, supplement or wavier does not adversely affect the rights, duties, liabilities or immunities of the Trustee or the Collateral Agent, as applicable. The Issuer may not sign an amendment, supplement or waiver until the Board of Directors of the Issuer approves it. In executing any amendment, supplement or waiver, the Trustee and the Collateral Agent shall be provided with and (subject to Section 7.01 hereof) shall be fully protected in relying upon, in addition to the documents required by Section 12.02 hereof, an Officer’s Certificate and an Opinion of Counsel each stating that the execution of such amended or supplemental indenture or security documents or intercreditor agreements, or waiver, is authorized or permitted by this Indenture.

 

135


ARTICLE 10

GUARANTEES

Section 10.01 Guarantee.

(a) Subject to this Article 10, each of the Guarantors hereby, jointly and severally, unconditionally guarantees to each Holder and to the Trustee and its successors and assigns, irrespective of the validity and enforceability of this Indenture, the Notes or the obligations of the Issuer hereunder or thereunder, that:

(1) the principal of, premium, if any, on, and interest, if any, on the Notes of the applicable series will be promptly paid in full when due, whether at maturity, by acceleration, redemption or otherwise, and interest on the overdue principal of, premium on, if any, interest, if any, on, the Notes of such series, if lawful, and all other obligations of the Issuer to the Holders or the Trustee hereunder or thereunder will be promptly paid in full or performed, all in accordance with the terms hereof and thereof; and

(2) in case of any extension of time of payment or renewal of any Notes of a series or any of such other obligations, that same will be promptly paid in full when due or performed in accordance with the terms of the extension or renewal, whether at stated maturity, by acceleration or otherwise.

Failing payment when due of any amount so guaranteed or any performance so guaranteed for whatever reason, the Guarantors will be jointly and severally obligated to pay the same immediately. Each Guarantor agrees that this is a guarantee of payment and not a guarantee of collection.

(b) The Guarantors hereby agree that their obligations hereunder are unconditional, irrespective of the validity, regularity or enforceability of the Notes or this Indenture, the absence of any action to enforce the same, any waiver or consent by any Holder with respect to any provisions hereof or thereof, the recovery of any judgment against the Issuer, any action to enforce the same or any other circumstance which might otherwise constitute a legal or equitable discharge or defense of a guarantor. Each Guarantor hereby waives diligence, presentment, demand of payment, filing of claims with a court in the event of insolvency or bankruptcy of the Issuer, any right to require a proceeding first against the Issuer, protest, notice and all demands whatsoever and covenant that this Guarantee will not be discharged except by complete performance of the obligations contained in the Notes and this Indenture.

(c) If any Holder or the Trustee is required by any court or otherwise to return to the Issuer, the Guarantors or any custodian, trustee, liquidator or other similar official acting in relation to either the Issuer or the Guarantors, any amount paid by either to the Trustee or such Holder, this Guarantee, to the extent theretofore discharged, will be reinstated in full force and effect.

 

136


(d) Each Guarantor agrees that it will not be entitled to any right of subrogation in relation to the Holders in respect of any obligations guaranteed hereby until payment in full of all obligations guaranteed hereby. Each Guarantor further agrees that, as between the Guarantors, on the one hand, and the Holders and the Trustee, on the other hand, (1) the maturity of the obligations guaranteed hereby may be accelerated as provided in Article 6 hereof for the purposes of this Guarantee, notwithstanding any stay, injunction or other prohibition preventing such acceleration in respect of the obligations guaranteed hereby, and (2) in the event of any declaration of acceleration of such obligations as provided in Article 6 hereof, such obligations (whether or not due and payable) will forthwith become due and payable by the Guarantors for the purpose of this Guarantee. The Guarantors will have the right to seek contribution from any non-paying Guarantor so long as the exercise of such right does not impair the rights of the Holders under the Guarantee.

Section 10.02 Limitation on Guarantor Liability.

Each Guarantor, and by its acceptance of Notes, each Holder, hereby confirms that it is the intention of all such parties that the Guarantee of such Guarantor not constitute a fraudulent transfer or conveyance for purposes of Bankruptcy Law, the Uniform Fraudulent Conveyance Act, the Uniform Fraudulent Transfer Act or any similar federal or state law to the extent applicable to any Guarantee. To effectuate the foregoing intention, the Trustee, the Holders and the Guarantors hereby irrevocably agree that the obligations of such Guarantor will be limited to the maximum amount that will, after giving effect to such maximum amount and all other contingent and fixed liabilities of such Guarantor that are relevant under such laws, and after giving effect to any collections from, rights to receive contribution from or payments made by or on behalf of any other Guarantor in respect of the obligations of such other Guarantor under this Article 10, result in the obligations of such Guarantor under its Guarantee not constituting a fraudulent transfer or conveyance.

Section 10.03 Execution and Delivery of Guarantee.

To evidence its Guarantee set forth in Section 10.01 hereof, each Guarantor hereby agrees that this Indenture or, if applicable, a Supplemental Indenture substantially in the form of Exhibit E, shall be executed on behalf of such Guarantor by an Officer of such Guarantor.

If an Officer whose signature is on this Indenture no longer holds that office at the time the Trustee authenticates the Note, the Guarantee will be valid nevertheless.

The delivery of any Note by the Trustee, after the authentication thereof hereunder, will constitute due delivery of the Guarantee set forth in this Indenture on behalf of the Guarantors.

Section 10.04 Releases.

The Guarantee of a Guarantor will be released and discharged automatically and unconditionally:

(a) upon the sale, disposition, exchange or other transfer (including through merger, consolidation or otherwise) of the Capital Stock of the Guarantor, after which such Guarantor is no longer a Restricted Subsidiary, or all or substantially all of the assets of such Guarantor (other than to the Issuer or a Restricted Subsidiary) if such sale, disposition, exchange or other transfer is not prohibited by this Indenture, and the release is otherwise not prohibited by this Indenture;

 

137


(b) upon the liquidation, winding up or dissolution of such Guarantor or the merger or consolidation of such Guarantor with and into the Issuer or another Guarantor in accordance with the applicable provisions of this Indenture;

(c) following delivery at any time by the Issuer to the Trustee of an Officer’s Certificate to the effect that the aggregate amount of Indebtedness for borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit then outstanding of such Guarantor (other than any such Indebtedness owed to the Issuer or any Guarantor) does not exceed $250.0 million (excluding the Notes, and excluding any other Indebtedness that will be released or discharged with respect to such Guarantor substantially concurrently with any release pursuant to this clause (c)); provided that such Guarantee will be reinstated if and to the extent required under Section 4.16 subsequent to such release;

(d) upon Legal Defeasance or satisfaction and discharge of the Notes as provided in Section 8.02 and Article 11;

(e) upon the occurrence of a Covenant Suspension Event, provided that if, after any Covenant Suspension Event, a Reversion Date shall occur, then the Suspension Period with respect to such Covenant Suspension Event shall terminate and all actions reasonably necessary to provide that the Notes shall have been unconditionally guaranteed by such Guarantor (if and to the extent such guarantee is required pursuant to Section 4.16) shall be taken within 90 days after such Reversion Date or as soon as reasonably practicable thereafter;

(f) upon the occurrence of any event after which such Guarantor is no longer a Restricted Subsidiary;

(g) if the Issuer designates such Guarantor as an Unrestricted Subsidiary in accordance with the applicable provisions of this Indenture; or

(h) as set forth in Article 9 or in accordance with the provisions of any Applicable Intercreditor Agreement then in effect with respect to the Notes.

The Trustee shall not be required to execute any document or give any confirmation as to or otherwise evidence any release or discharge of any Guarantee unless and until (1) requested in writing to do so by the Issuer and (2) the Issuer delivers an Officer’s Certificate and an Opinion of Counsel to the Trustee stating that all conditions precedent to the release and discharge of the Guarantee have been satisfied.

 

138


ARTICLE 11

SATISFACTION AND DISCHARGE

Section 11.01 Satisfaction and Discharge.

This Indenture will be discharged and will cease to be of further effect as to all Notes of any series issued hereunder, when:

(a) either:

(1) all Notes of the applicable series that have been authenticated, except lost, stolen or destroyed Notes of such series that have been replaced or paid and Notes of such series for whose payment money has been deposited in trust or segregated and held in trust by the Issuer and thereafter repaid to the Issuer, have been delivered to the Trustee for cancellation; or

(2) all Notes of the applicable series that have not been delivered to the Trustee for cancellation have become due and payable by reason of the mailing or transmitting of a notice of redemption or otherwise or will become due and payable within one year or are to be called for redemption within one year under irrevocable arrangements for the giving of notice of redemption by the Trustee in the name, and at the expense, of the Issuer, and the Issuer or any Guarantor has irrevocably deposited or caused to be deposited with the Trustee as trust funds in trust solely for the benefit of the Holders of the Notes of such series, cash in U.S. dollars, non-callable Government Securities, or a combination thereof, in such amounts as will be sufficient, without consideration of any reinvestment of interest, to pay and discharge the entire Indebtedness on the Notes of the applicable series not delivered to the Trustee for cancellation for principal, premium, if any, and interest, if any, to the date of maturity or redemption;

(b) in respect of subclause (2) of clause (a) of this Section 11.01, no Event of Default with respect to the applicable series of Notes has occurred and is continuing on the date of the deposit (other than an Event of Default resulting from the borrowing of funds to be applied to such deposit and any similar and simultaneous deposit relating to other Indebtedness and, in each case, the granting of Liens to secure such borrowings) and the deposit will not result in a breach or violation of, or constitute a default under, any other instrument to which the Issuer or any Guarantor is a party or by which the Issuer or any Guarantor is bound (other than with respect to the borrowing of funds to be applied concurrently to make the deposit required to effect such satisfaction and discharge and any similar concurrent deposit relating to other Indebtedness, and in each case the granting of Liens to secure such borrowings);

(c) the Issuer or any Guarantor has paid or caused to be paid all sums payable by it under this Indenture with respect to the Notes of the applicable series; and

(d) the Issuer has delivered irrevocable written instructions to the Trustee under this Indenture to apply the deposited money toward the payment of the Notes of the applicable series at maturity or on the redemption date, as the case may be.

In addition, the Issuer must deliver an Officer’s Certificate and an Opinion of Counsel to the Trustee to the effect that all conditions precedent to satisfaction and discharge of the Notes of the applicable series have been complied with.

 

139


Notwithstanding the satisfaction and discharge of this Indenture, if money has been deposited with the Trustee pursuant to subclause (2) of clause (a) of this Section 11.01, the provisions of Sections 11.02 and 8.06 hereof will survive. In addition, nothing in this Section 11.01 will be deemed to discharge those provisions of Section 7.07 hereof, that, by their terms, survive the satisfaction and discharge of this Indenture.

Section 11.02 Application of Trust Money.

Subject to the provisions of Section 8.06 hereof, all money deposited with the Trustee pursuant to Section 11.01 hereof shall be held in trust and applied by it, in accordance with the provisions of the Notes of the applicable series and this Indenture, to the payment, either directly or through any Paying Agent (including the Issuer acting as its own Paying Agent) as the Trustee may determine, to the Persons entitled thereto, of the principal, premium, if any, interest, if any, for whose payment such money has been deposited with the Trustee; but such money need not be segregated from other funds except to the extent required by law.

If the Trustee or Paying Agent is unable to apply any money or Government Securities in accordance with Section 11.01 hereof by reason of any legal proceeding or by reason of any order or judgment of any court or Governmental Authority enjoining, restraining or otherwise prohibiting such application, the Issuer’s and any Guarantor’s obligations under this Indenture and the Notes of the applicable series shall be revived and reinstated as though no deposit had occurred pursuant to Section 11.01 hereof; provided that if the Issuer has made any payment of principal of, premium on, if any, or interest, if any, on, any Notes of such series because of the reinstatement of its obligations, the Issuer shall be subrogated to the rights of the Holders of such Notes to receive such payment from the money or Government Securities held by the Trustee or Paying Agent.

ARTICLE 12

COLLATERAL AND SECURITY

Section 12.01 General.

The Notes are, and any Guarantees will be, secured on a first-priority basis (subject to permitted encumbrances) by Liens on the Collateral, other than, in each case, during any Suspension Period with respect to a series of Notes. The Liens securing the Notes and the Guarantees will be shared equally and ratably (subject to Liens permitted to be incurred under Section 4.12) with the holders of other First Lien Obligations.

Section 12.02 Security Documents.

(a) In order to secure the due and punctual payment of the Note Obligations, when the same shall be due and payable, whether on an Interest Payment Date, at maturity, by acceleration, repurchase, redemption or otherwise, and interest on the overdue principal of and interest (to the extent permitted by law) on the Notes and performance of all other Note Obligations, (i) the Issuer has, on the Issue Date, entered into Security Documents granting the Collateral Agent a Lien on (A) substantially all the existing and future tangible and intangible assets and rights of the Issuer and the Guarantors, if any (other than, in each case, Excluded Assets) and (B) Equity Interests in all direct Subsidiaries of the Issuer and each Guarantor, if any (other than, in each case, Excluded Capital Stock), and (ii) the Issuer agrees that it shall take all such action as shall be required to ensure that the Note Obligations will (other than, in each case, during any Suspension Period with respect to a series of Notes) be secured by a Lien, subject only to Permitted Liens, on the Collateral.

 

140


(b) To the extent, but only to the extent, permitted hereby, the Issuer and the Guarantors may incur Additional First Lien Obligations. Any additional class or series of Additional First Lien Obligations will be secured by Liens on the Collateral that rank pari passu with the Liens securing First Lien Obligations, in each case, under and pursuant to the Security Documents, once the Senior Class Debt Representative with respect to any such class or series of Additional First Lien Obligations, acting on behalf of the holders of such series of Additional First Lien Obligations, (1) becomes a party to a First Lien Intercreditor Agreement by satisfying the conditions set forth therein and (2) becomes a party to the Collateral Agency Agreement.

(c) If the Issuer or any of the Guarantors incurs Additional First Lien Obligations, the Issuer, the Guarantors (if any), the Collateral Agent, on behalf of itself, the Trustee, on behalf of the Holders of the Notes, the other Senior Class Debt Representatives, acting on behalf of the holders of the applicable series of Additional First Lien Obligations, and the other agents (if any) will enter into a first lien intercreditor agreement, substantially in the form attached hereto as Exhibit F or which otherwise constitutes a first lien intercreditor agreement that is an Applicable Intercreditor Agreement (any such first lien intercreditor agreement, the “First Lien Intercreditor Agreement”).

(d) If the Issuer or any of the Guarantors incurs Indebtedness secured by a Lien on the Collateral that is junior in priority relative to the Liens on the Collateral securing the First Lien Obligations, the Issuer, the Guarantors, the Collateral Agent, acting on behalf of itself, the Trustee, acting on behalf of the Holders of the Notes, the other collateral agents (if any) and the applicable Junior Lien Representative, on behalf of itself and the applicable Junior Lien Secured Parties, will enter into a junior lien intercreditor agreement, substantially in the form attached hereto as Exhibit G or which otherwise constitutes a junior lien intercreditor agreement that is an Applicable Intercreditor Agreement (any such junior lien intercreditor agreement, the “Junior Lien Intercreditor Agreement”).

(e) The Note Documents (other than any Applicable Intercreditor Agreement) will be subject to the terms, limitations and conditions set forth in each Applicable Intercreditor Agreement. Each Holder of Notes, by its acceptance of a Note, is deemed to (i) have consented and agreed to the terms of each Security Document (including each Applicable Intercreditor Agreement, if any, entered into after the Issue Date in accordance with clauses (c) and (d) of this Section 12.02), as originally in effect and as amended, supplemented or replaced from time to time in accordance with its terms or the terms of this Indenture or, if applicable, each Applicable Intercreditor Agreement, (ii) have authorized and directed the Trustee to enter into (A) the Collateral Agency Agreement on the Issue Date and (B) each Applicable Intercreditor Agreement at any time after the Issue Date in accordance with clauses (c) and (d) of this Section 12.02, (iii) have consented to the appointment of the Collateral Agent pursuant to the Collateral Agency Agreement, (iv) have authorized and directed the Collateral Agent to enter into the Security Documents to which it is, or is intended to be, a party, and (v) have authorized and empowered the Collateral Agent (through the Collateral Agency Agreement and each Applicable Intercreditor Agreement, if any) to bind the Holders of Notes as set forth in the Security Documents to which they are a party and to perform its obligations and exercise its rights and powers thereunder, including entering into amendments permitted by the terms of the Note Documents. To the extent that any provision of the Note Documents is not consistent with or contradicts the Collateral Agency Agreement (or the Applicable Intercreditor Agreements (if any)), the Collateral Agency Agreement and/or the Applicable Intercreditor Agreements (if any) shall govern.

 

141


(f) Each Holder of Notes, by its acceptance of a Note, is deemed to have:

(1) authorized, consented to and directed the Trustee to enter into the Collateral Agency Agreement;

(2) other than during any Suspension Period, agreed (in its capacity as a Holder of Notes) that it is subject to and bound by the provisions of the Collateral Agency Agreement and each Applicable Intercreditor Agreement in effect at any time;

(3) authorized the Collateral Agent’s execution and delivery of the Security Documents to be dated as of the date hereof (in accordance with the Collateral Agency Agreement);

(4) consented and agreed that the Collateral Agent may execute and deliver any additional Security Documents (including any Applicable Intercreditor Agreement) not in effect as of the date hereof and act in accordance with the terms thereof;

(5) consented and agreed that the Collateral Agent may, in its sole discretion and without the consent of the Trustee or the Holders, take all actions it deems necessary or appropriate in order to:

(A) enforce any of the terms of the Security Documents; and

(B) collect and receive any and all amounts payable in respect of the Note Obligations of the Issuer and the Guarantors to the Holders, the Collateral Agent or the Trustee under the Note Documents.

Section 12.03 Recording, Registration and Opinions; Trustees Disclaimer Regarding Collateral.

(a) Unless the Collateral has been released (including during a Suspension Period), the Issuer and, if applicable, any Guarantors, shall take or cause to be taken all actions required pursuant to the terms of the Security Documents to perfect, maintain, preserve and protect the Lien on the Collateral granted by the Collateral Documents (subject only to Permitted Liens and to the terms of the Security Documents), including without limitation arranging for the filing of financing statements, continuation statements and any instruments of further assurance, in such manner and in such places as may be required by law fully to preserve and protect the rights of the Holders, the Trustee and the Collateral Agent under the Note Documents to all property now or hereafter at any time comprising the Collateral. The Issuer shall from time to time promptly pay all financing, continuation statements, registration and/or filing fees, charges and taxes relating to the Note Documents, any amendments thereto and any other instruments of further assurance required hereunder or pursuant to the Collateral Documents. Neither the Trustee nor the Collateral Agent shall have any obligation to, and neither of them shall be responsible for any failure to, so register, file or record.

 

142


(b) [Reserved.]

(c) Notwithstanding anything to the contrary set forth in the Note Documents, neither the Trustee nor the Collateral Agent shall be responsible for the existence, genuineness or value of any of the Collateral, or for the creation, validity, perfection, priority or enforceability of the Liens in any of the Collateral, whether impaired by operation of law or by reason of any action or omission to act on its part hereunder, for the validity or sufficiency of the Collateral or any agreement or assignment contained therein, for the validity of the title of the Issuer to the Collateral, for insuring the Collateral or for the payment of taxes, charges, assessments or Liens upon the Collateral or otherwise as to the maintenance of the Collateral.

(d) The Trustee shall have no duty to ascertain or inquire as to the performance or observance of any of the terms of this Indenture or any Security Document by the Issuer, any Guarantor or any other Person that is a party thereto or bound thereby. The Trustee shall not be responsible or liable for seeing to or monitoring the attachment, perfection, or priority of any lien or security interest created or intended to be created in the Collateral hereby or by any of the Security Documents. The Trustee shall not be responsible for the preparation, correctness, filing, re-filing, recording or re-recording of any security documents or instruments, including UCC financing statements or continuation statements in any public office at any time or times or otherwise perfecting or maintaining the perfection of any lien or security interest in any of the Collateral.

Section 12.04 Possession, Use and Release of Collateral.

(a) Each Holder, by accepting a Note, consents and agrees to the provisions of the Note Documents governing the possession, use and release of Collateral. Each Holder, by accepting a Note, consents and agrees that Collateral may, and, as applicable, shall, be released or substituted in accordance with the terms of the Security Documents.

(b) The Liens on the Collateral in favor of the Collateral Agent with respect to all obligations of the Issuer and the Guarantors secured by such Collateral will be released automatically and unconditionally:

(1) upon payment in full of all outstanding Notes and all other amounts due under this Indenture (including any Guarantee), the Collateral Agency Agreement and the Notes;

(2) upon legal defeasance or satisfaction and discharge of the Notes as set forth under Articles 8 and 11, respectively;

(3) as to any Collateral that constitutes all or substantially all of the Collateral, with the consent of the holders of at least two-thirds in principal amount of the Notes then outstanding;

 

143


(4) to enable the Issuer and/or any Guarantor to consummate the disposition of property or assets to a Person other than the Issuer or a Guarantor (unless such property or other assets transferred to a Person that is the Issuer or a Guarantor are automatically, substantially concurrently with or in advance of such release, the subject of Liens granted by such transferee securing the Notes) to the extent not prohibited under Section 4.10;

(5) in the case of a sale or other transfer as part of or in connection with an Asset Sale by the Issuer or any Guarantor to a Person other than the Issuer or a Guarantor (unless such property or other assets transferred to a Person that is the Issuer or a Guarantor are automatically, substantially concurrently with or in advance of such release, the subject of Liens granted by such transferee securing the Notes) in a transaction permitted hereunder;

(6) with respect to any Collateral owned by a Guarantor whose Capital Stock is sold or otherwise disposed of in accordance with the terms of this Indenture to a Person that is not (either before or after giving effect to such transaction) the Issuer or a Restricted Subsidiary, upon such sale or other disposition;

(7) upon the occurrence of a Covenant Suspension Event, provided that, if, after any Covenant Suspension Event, a Reversion Date shall occur, then the Suspension Period with respect to such Covenant Suspension Event shall terminate and the Issuer will take all actions reasonably necessary to provide that the Notes and any Guarantees shall be secured on a first-priority basis (subject to permitted encumbrances) by Liens on the Collateral within 120 days after such Reversion Date or as soon as reasonably practicable thereafter (but in each case, subject to all limitations and exclusions set forth herein and in the Security Documents);

(8) with respect to property or other assets owned by a Guarantor that is released from its Guarantee pursuant to the terms of this Indenture, concurrently upon the release from such Guarantee;

(9) with respect to property or other assets that does not constitute Collateral (or ceases to constitute Collateral) (including by being or becoming an Excluded Asset); and

(10) as required by the terms of any Applicable Intercreditor Agreement.

(c) At the request of the Issuer, and upon delivery of an Officer’s Certificate and Opinion of Counsel delivered to the Trustee in accordance with in the requirements specified in this Indenture, the Trustee will execute and deliver any documents, instructions or instruments evidencing the consent of the Holders (and the Holders will be deemed to have consented to and authorized the Trustee to execute and deliver any such documentation, instructions or instruments) to any permitted release contemplated by Section 12.04(b). Each Holder of Notes, by its acceptance of a Note, is deemed to have irrevocably consented to and authorized the Trustee and the Collateral Agent to execute and deliver any such documentation, instructions or instruments relating to any such permitted release under this Indenture or the Security Documents.

 

144


(d) The Collateral Agent or the Trustee, as applicable, shall execute and deliver all such authorizations, instructions and other instruments and take such actions (and the Holders will be deemed to have consented to and authorized the Collateral Agent or the Trustee, as applicable, to execute and deliver any such authorization, instruction or instrument and take any such action) under the Security Documents or otherwise as may be reasonably requested in writing by the Issuer, at the cost of the Issuer, to evidence, confirm and effectuate any release of Collateral provided for in Section 12.04(b); provided that the Trustee and the Collateral Agent shall be entitled to receive an Opinion of Counsel and an Officer’s Certificate in connection with any such request of the Issuer related to the release of any Collateral.

Section 12.05 Suits to Protect the Collateral

Subject to the provisions of Article 7 and the Security Documents, the Trustee may or may direct the Collateral Agent to take all actions it determines in order to:

(a) enforce any of the terms of the Security Documents; and

(b) collect and receive any and all amounts payable in respect of the Obligations hereunder.

Subject to the provisions of the Security Documents, the Trustee and the Collateral Agent shall have power to institute and to maintain such suits and proceedings as the Trustee or the Collateral Agent may determine to prevent any impairment of the Collateral by any acts which may be unlawful or in violation of any of the Security Documents or this Indenture, and such suits and proceedings as the Trustee or the Collateral Agent may determine to preserve or protect its interests and the interests of the Holders in the Collateral. Nothing in this Section 12.05 shall be considered to impose any such duty or obligation to act on the part of the Trustee or the Collateral Agent.

Section 12.06 Authorization of Receipt of Funds by the Trustee Under the Security Documents.

Subject to the provisions of any Applicable Intercreditor Agreement, the Trustee is authorized to receive any funds for the Notes Parties distributed under the Security Documents, and to make further distributions of such funds to the Holders according to the provisions of this Indenture.

Section 12.07 Purchaser Protected.

No purchaser or grantee of any property or rights purporting to be released herefrom shall be bound to ascertain the authority of the Trustee or the Collateral Agent to execute the release or to inquire as to the existence of any conditions herein prescribed for the exercise of such authority; nor shall any purchaser or grantee of any property or rights permitted by this Indenture to be sold or otherwise disposed of by the Issuer or any Guarantor be under any obligation to ascertain or inquire into the authority of the Issuer or such Guarantor to make such sale or other disposition.

 

145


ARTICLE 13

MISCELLANEOUS

Section 13.01 Notices.

Any notice or communication by the Issuer, any Guarantor or the Trustee to the others is duly given if in writing and delivered in Person or by first class mail (registered or certified, return receipt requested), facsimile transmission, electronic mail or overnight air courier guaranteeing next day delivery, to the others’ address:

If to the Issuer and/or any Guarantor:

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

E-mail: [***]

Attention: Chief Financial Officer and General Counsel

With a copy to:

Davis Polk & Wardwell LLP

450 Lexington Avenue

New York, NY 10017

E-mail: [***]

Attention: [***]

If to the Trustee:

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Facsimile No.: [***]

E-mail: [***]

Attention: Corporate Trust Administration

The Issuer, any Guarantor or the Trustee, by notice to the others, may designate additional or different addresses for subsequent notices or communications.

All notices and communications (other than those sent to Holders) will be deemed to have been duly given: at the time delivered by hand, if personally delivered; five Business Days after being deposited in the mail, postage prepaid, if mailed; when receipt acknowledged, if transmitted by facsimile; at the time sent, if transmitted by electronic mail; and the next Business Day after timely delivery to the courier, if sent by overnight air courier guaranteeing next day delivery; provided that all notices and communications to the Trustee shall not be deemed received by the Trustee unless actually received by the Trustee at its address, facsimile number or electronic mail address set forth above.

 

146


Any notice or communication to a Holder will be mailed by first class mail, or by certified or registered mail, return receipt requested, or by overnight air courier guaranteeing next day delivery to its address shown on the register kept by the Registrar. Failure to mail a notice or communication to a Holder or any defect in it will not affect its sufficiency with respect to other Holders.

If a notice or communication is mailed in the manner provided above within the time prescribed, it is duly given, whether or not the addressee receives it.

If the Issuer mails a notice or communication to Holders, it will send a copy to the Trustee and each Agent at the same time by any of the means described above with respect to notice or communication by the Issuer.

Section 13.02 Certificate and Opinion as to Conditions Precedent.

Upon any request or application by the Issuer to the Trustee to take any action under any Note Document, the Issuer shall furnish to the Trustee:

(1) an Officer’s Certificate in form reasonably satisfactory to the Trustee (which must include the statements set forth in Section 13.03) stating that, in the opinion of the signers, all conditions precedent and covenants, if any, provided for in the relevant Note Document(s) relating to the proposed action have been complied with; and

(2) an Opinion of Counsel in form reasonably satisfactory to the Trustee (which must include the statements set forth in Section 13.03) stating that, in the opinion of such counsel, all such conditions precedent and covenants have been complied with, provided, that no such Opinion of Counsel shall be delivered on the date of this Indenture in connection with the original issuance of the initial Global Notes.

The Trustee shall, to the extent permitted by Sections 7.01 and 7.02, be entitled to rely upon, as conclusive evidence of compliance with the foregoing provisions the appropriate statements contained in such documents and such Opinion of Counsel.

Section 13.03 Statements Required in Certificate or Opinion.

Each certificate or opinion with respect to compliance with a condition or covenant provided for in this Indenture and must include:

(1) a statement that the Person making such certificate or opinion has read such covenant or condition;

(2) a brief statement as to the nature and scope of the examination or investigation upon which the statements or opinions contained in such certificate or opinion are based;

(3) a statement that, in the opinion of such Person, he or she has made such examination or investigation as is necessary to enable him or her to express an informed opinion as to whether or not such covenant or condition has been complied with; and

 

147


(4) a statement as to whether or not, in the opinion of such Person, such condition or covenant has been complied with.

Section 13.04 Rules by Trustee and Agents.

The Trustee may make reasonable rules for action by or at a meeting of Holders. The Registrar or Paying Agent may make reasonable rules and set reasonable requirements for its functions.

Section 13.05 No Personal Liability of Directors, Managers, Officers, Members, Partners, Employees and Equityholders.

No past, present or future director, officer, manager, employee, incorporator, member, partner or direct or indirect stockholder, member or unitholder of the Issuer or any Restricted Subsidiaries or of any of their direct or indirect parent companies, as such, will have any liability for any obligations of the Issuer or the Guarantors under the Notes, this Indenture, the Guarantees or any Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

Section 13.06 Governing Law; Waiver of Trial by Jury; Jurisdiction.

(a) THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THIS INDENTURE, THE NOTES AND THE GUARANTEES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5- 1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

(b) Each of the Issuer, any Guarantors and the Trustee, and each Holder of a Note, by its acceptance thereof, hereby irrevocably waives, to the fullest extent permitted by applicable law, any and all right it may have to trial by jury in any legal proceeding directly or indirectly arising out of or relating to this Indenture, the securities or the transactions contemplated hereby or thereby.

(c) Each of the Issuer and each Guarantor, if any, irrevocably consents and submits, for itself and in respect of any of its assets or property, to the non-exclusive jurisdiction of any court of the State of New York or any United States federal court sitting, in each case, in the Borough of Manhattan, the City of New York, New York, United States of America, and any appellate court from any thereof in any suit, action or proceeding that may be brought in connection with this Indenture or the securities, and waives any immunity from the jurisdiction of such courts. Each of the Issuer and each Guarantor, if any, irrevocably waives, to the fullest extent permitted by law, any objection to any such suit, action or proceeding that may be brought in such courts whether on the grounds of venue, residence or domicile or on the ground that any such suit, action or proceeding has been brought in an inconvenient forum. Each of the Issuer and each Guarantor, if any, agrees, to the fullest extent that it lawfully may do so, that final judgment in any such suit, action or proceeding brought in such a court shall be conclusive and binding upon the Issuer and any Guarantor, if any, as applicable, and each of the Issuer and any Guarantor, if any, waives, to the fullest extent permitted by law, any objection to the enforcement by any competent court in

 

148


the Issuer’s and the applicable Guarantor’s, as applicable, jurisdiction of organization of judgments validly obtained in any such court in New York on the basis of such suit, action or proceeding; provided, however, that neither the Issuer nor any Guarantor waive, and the foregoing provisions of this sentence shall not constitute or be deemed to constitute a waiver of, (i) any right to appeal any such judgment, to seek any stay or otherwise to seek reconsideration or review of any such judgment or (ii) any stay of execution or levy pending an appeal from, or a suit, action or proceeding for reconsideration of, any such judgment.

Section 13.07 No Adverse Interpretation of Other Agreements.

This Indenture may not be used to interpret any other indenture, loan or debt agreement of the Issuer or its Subsidiaries or of any other Person. Any such indenture, loan or debt agreement may not be used to interpret this Indenture.

Section 13.08 Successors.

All agreements of the Issuer in this Indenture and the Notes will bind its successors. All agreements of the Trustee in this Indenture will bind its successors. All agreements of each Guarantor in this Indenture will bind its successors, except as otherwise provided in Article 10 hereof.

Section 13.09 Severability.

In case any provision in this Indenture or in the Notes is invalid, illegal or unenforceable, the validity, legality and enforceability of the remaining provisions will not in any way be affected or impaired thereby.

Section 13.10 Execution; Counterpart Originals.

The parties may manually or electronically sign any number of copies of this Indenture. Each signed copy will be an original, but all of them together represent the same agreement. The exchange of copies of this Indenture and of signature pages by facsimile or electronic format (i.e., “pdf” or “tif”) transmission shall constitute effective execution and delivery of this Indenture as to the parties hereto and may be used in lieu of the original Indenture for all purposes. Signatures of the parties hereto transmitted by facsimile or electronic format (i.e., “pdf” or “tif”) shall be deemed to be their original signatures for all purposes. Delivery of an executed Indenture by one party to any other party may be made by facsimile, electronic mail (including any electronic signature complying with the New York Electronic Signatures and Records Act (N.Y. State Tech. §§ 301- 309), as amended from time to time, or other applicable law), including DocuSign, or other transmission method, and the parties hereto agree that any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

Section 13.11 Table of Contents, Headings, etc.

The Table of Contents and Headings of the Articles and Sections of this Indenture have been inserted for convenience of reference only, are not to be considered a part of this Indenture and will in no way modify or restrict any of the terms or provisions hereof.

 

149


Section 13.12 Tax Matters. Each of the parties hereto agree to cooperate and to provide the other with such information as each may have in its possession to enable the determination of whether any payments pursuant to this Indenture are subject to the withholding requirements described in Section 1471(b) of the Code or otherwise imposed pursuant to Sections 1471 through 1474 of the Code and any regulations, or agreements thereunder or official interpretations thereof (“Applicable Tax Law”). The Trustee shall be entitled to make any withholding or deduction from payments under this Indenture to the extent necessary to comply with Applicable Tax Law.

[Signatures on following page]

 

150


SIGNATURES

Dated as of May 26, 2023

 

VENTURE GLOBAL LNG, INC.
By:   /s/ Jonathan W. Thayer
Name:   Jonathan W. Thayer
Title:   Chief Financial Officer

 

[Signature page to Indenture]


THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee

By:

 

/s/ Terrence T. Rawlins

Name:

 

Terrence T. Rawlins

Title:

 

Vice President

 

 

[Signature page to Indenture]


EXHIBIT A-1

[Face of Note]

 

[Insert the Global Note Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Private Placement Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Regulation S Temporary Note Legend, if applicable pursuant to the provisions of the indenture]

 

A1-1


CUSIP       1

ISIN       2

8.125% Senior Secured Notes due 2028

 

No.             [Initially]3 $      

VENTURE GLOBAL LNG, INC.

promises to pay to [Cede & Co.]4 [       ] or registered assigns, the principal sum [of               UNITED STATES DOLLARS] or [as set forth on the Schedule of Exchanges of Interests in the Global Note attached hereto]5 on June 1, 2028.

Interest Payment Dates:  June 1 and December 1

Record Dates:      May 15 and November 15

Additional provisions of this Note are set forth on the other side of this Note.

 

 

1 

92332YAA9 (Rule 144A); U9220NAA9 (Reg S).

2 

US92332YAA91 (Rule 144A); USU9220NAA91 (Reg S).

3 

Include only if the Note is issued in global form.

4 

Include only if the Note is issued in global form.

5 

Include only if the Note is issued in global form.

 

A1-2


IN WITNESS HEREOF, the Issuer has caused this instrument to be duly executed.

Dated:       

 

VENTURE GLOBAL LNG, INC.
By:    
  Name:
  Title:

 

This is one of the Notes referred

to in the within-mentioned Indenture:

The Bank of New York Mellon Trust Company, N.A.,

as Trustee

By:    
  Authorized Signatory

 

A1-3


[Back of Note]

8.125% Senior Secured Notes due 2028

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global LNG, Inc., a Delaware corporation (the “Issuer”), promises to pay or cause to be paid interest on the principal amount of this Note at 8.125% per annum from [May 26, 2023]6 until maturity. The Issuer will pay interest, if any, semi-annually in arrears on June 1 and December 1 of each year, beginning on [December 1, 2023]7, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). The Issuer will make each interest payment to the Holder of record of this Note on the immediately preceding June 1 and December 1 (whether or not a Business Day) (each, a “Record Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from [May 26, 2023].8

Interest will be computed on the basis of a 360-day year comprised of twelve 30-day months.

(2) METHOD OF PAYMENT. The Issuer will pay interest on the Notes (except defaulted interest), if any, to the Persons who are registered Holders at the close of business on the May 15 or November 15 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium, if any, and interest, if any, at the office or agency of the Paying Agent and Registrar within the City and State of New York, or, at the option of the Issuer, payment of interest, if any, may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that (a) all cash payments of principal, premium, if any, and interest with respect to Notes represented by Global Notes registered in the name of or held by DTC or its nominee will be made through the Paying Agent by wire transfer of immediately available funds to the accounts specified by the registered Holder or Holders thereof and (b) all cash payments of principal, premium, if any, and interest with respect to certificated Notes may, at the option of the Issuer, be made by wire transfer to a U.S. dollar account maintained by the payee with a bank in the United States of America if such Holder elects payment by wire transfer by giving written notice to the Trustee or the Paying Agent to such effect designating such account no later than 30 days immediately preceding the relevant due date for payment (or such other date as the Trustee may accept in its discretion). Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

 

6 

In the case of Notes issued on the Issue Date.

7 

In the case of Notes issued on the Issue Date.

8 

In the case of Notes issued on the Issue Date.

 

A1-4


(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Issuer may change the Paying Agent or Registrar without prior notice to the Holders. The Issuer or any of its Subsidiaries may act as Paying Agent or Registrar.

(4) INDENTURE. The Issuer issued the Notes under an Indenture, dated as of May 26, 2023 (the “Indenture”), among the Issuer, the Trustee and the Collateral Agent. The terms of the Notes include those stated in the Indenture. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are unsecured obligations of the Issuer. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

(a) At any time prior to June 1, 2025, the Issuer may on any one or more occasions redeem up to 40% of the aggregate principal amount of all Notes issued under the Indenture, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 108.125% of the principal amount of the Notes redeemed, plus accrued and unpaid interest, if any, to the date of redemption with an amount not to exceed the amount of net cash proceeds from one or more Equity Offerings consummated after the Issue Date; provided that:

(i) at least 50% of the aggregate principal amount of Notes issued under the Indenture on the Issue Date (excluding Notes held by the Issuer and its Subsidiaries) remains outstanding immediately after the occurrence of such redemption (unless all such Notes are otherwise repurchased or redeemed pursuant to another provision described under Article 3 of the Indenture); and

(ii) the redemption occurs within 180 days of the date of the closing of such Equity Offerings.

(b) At any time prior to June 1, 2025, the Issuer may on any one or more occasions redeem all or a part of the Notes, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 100% of the principal amount of the Notes redeemed, plus the Applicable Redemption Premium as of, and accrued and unpaid interest, if any, to the date of redemption.

(c) On or after June 1, 2025, the Issuer may on any one or more occasions redeem all or a part of the Notes, upon not less than 10 nor more than 60 days’ notice, at the redemption prices (expressed as percentages of principal amount) set forth below, plus accrued and unpaid interest, if any, on the Notes redeemed, to the applicable date of redemption, if redeemed during the twelve-month period beginning on June 1 of the years indicated below:

 

Year

  

Percentage

2025

   104.063%

2026

   102.031%

2027 and thereafter

   100.000%

 

A1-5


Unless the Issuer defaults in the payment of the redemption price, interest will cease to accrue on the Notes or portions thereof called for redemption on the applicable redemption date.

(6) MANDATORY REDEMPTION. The Issuer is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control Triggering Event, the Issuer will be required to make an offer (a “Change of Control Offer”) to each Holder to repurchase all or any part (equal to $2,000 or an integral multiple of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash (the “Change of Control Payment”) equal to 101% of the aggregate principal amount of Notes repurchased, plus accrued and unpaid interest, if any, on the Notes repurchased to, but not including, the date of purchase, subject to the rights of Holders of Notes on the relevant record date to receive interest due on the relevant Interest Payment Date. Within thirty days following any Change of Control Triggering Event, the Issuer will mail, or deliver electronically if the Notes are held at DTC, a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Issuer will be required to make a Collateral Asset Sale Offer or an Asset Sale Offer to the extent provided in Section 4.10 of the Indenture.

(8) NOTICE OF REDEMPTION. At least 10 days but not more than 60 days before a redemption date, the Issuer will mail or cause to be mailed, by first class mail (or, in the case of Global Notes, transmit with the procedures of the Depositary), a notice of redemption to each Holder (with a copy to the Trustee) whose Notes are to be redeemed at its registered address, except that redemption notices may be mailed or transmitted more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes or a satisfaction and discharge of the Indenture pursuant to Articles 8 or 11 thereof Notes and portions of Notes selected will be in amounts of $2,000 or whole multiples of $1,000 in excess thereof; except that if all of the Notes of a Holder are to be redeemed or purchased, the entire outstanding amount of Notes held by such Holder shall be redeemed or purchased.

Any such redemption may, at the Issuer’s discretion, be subject to one or more conditions precedent, including completion of any related Equity Offerings, Change of Control or other transaction. In addition, if such redemption is subject to the satisfaction of one or more conditions precedent, the related notice shall describe each such condition, and if applicable, shall state that, in the Issuer’s discretion, the date of redemption may be delayed until such time as any or all such conditions shall be satisfied or waived, or such redemption or purchase may not occur and such notice may be rescinded in the event that any or all such conditions shall not have been satisfied or waived by the date of redemption, or by the date of redemption as so delayed. In addition, the Issuer may provide in such notice that payment of the redemption price and performance of the Issuer’s obligations with respect to such redemption may be performed by another Person (it being understood that any such provision for payment by another Person will not relieve the Issuer and the Guarantors from their obligations with respect to such redemption).

 

A1-6


(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Issuer may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Issuer need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Issuer need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the next succeeding Interest Payment Date.

(10) PERSONS DEEMED OWNERS. The registered Holder may be treated as the owner of it for all purposes. Only registered Holders have rights under the Indenture.

(11) AMENDMENT, SUPPLEMENT AND WAIVER. Subject to certain exceptions, the Indenture, the Notes or the Guarantees may be amended or supplemented as provided in the Indenture.

(12) DEFAULTS AND REMEDIES. The Events of Default relating to the Notes are defined in Section 6.01 of the Indenture. If any Event of Default (other than an Event of Default of the type specified in clause (h) or (i) of Section 6.01 of the Indenture with respect to the Issuer) occurs and is continuing under the Indenture, the Trustee or the Holders of not less than 30% in aggregate principal amount of all of the then outstanding Notes may, by written notice to the Issuer and the Trustee, declare all of the Notes to be due and payable immediately. Upon any such declaration, the Notes shall become due and payable immediately. Notwithstanding the foregoing, in the case of an Event of Default arising under clause (h) or (i) of Section 6.01 of the Indenture with respect to the Issuer, all outstanding Notes will become due and payable immediately without further action or notice. Holders may not enforce the Indenture, the Notes, the Security Documents or the Guarantees except as provided in the Indenture. Subject to certain limitations, Holders of a majority in aggregate principal amount of all the Notes then outstanding may direct the Trustee in its exercise of any trust or power.

(13) TRUSTEE DEALINGS WITH ISSUER. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Issuer or its Affiliates, and may otherwise deal with the Issuer or its Affiliates, as if it were not the Trustee.

(14) GUARANTEES. The Issuer’s obligations under the Notes are fully and unconditionally guaranteed, jointly and severally, by the Guarantors, if any, to the extent set forth in Article 10 of the Indenture.

(15) SECURITY. The Notes and the related Guarantees, if any, will be secured by the Collateral on the terms and subject to the conditions set forth in the Indenture and the Security Documents. The Collateral Agent holds the Collateral in trust for the benefit of the Holders of the Notes, in each case pursuant to the Security Documents, the Collateral Agency Agreement and any Acceptable Intercreditor Agreement. Each Holder, by accepting this Note, consents and agrees to the terms of the Security Documents (including the provisions providing for the foreclosure and release of Collateral), the Collateral Agency Agreement and any Acceptable

 

A1-7


Intercreditor Agreement, each as may be in effect or may be amended from time to time in accordance with their terms and the Indenture, and authorizes and directs the Trustee, the Collateral Agent and any common collateral agent (if any) to enter into the Security Documents, the Collateral Agency Agreement and any Acceptable Intercreditor Agreement at any time after the Issue Date, if applicable, and to perform its obligations and exercise its rights thereunder in accordance therewith.

(16) NO RECOURSE AGAINST OTHERS. No director, officer, employee, incorporator or stockholder of the Issuer or any Guarantor, as such, will have any liability for any obligations of the Issuer or the Guarantors under the Notes, the Indenture, the Guarantees, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(17) AUTHENTICATION. This Note will not be entitled to any benefit under the Indenture or be valid or obligatory for any purposes until authenticated by the manual signature of the Trustee or an authenticating agent.

(18) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(19) CUSIP NUMBERS AND ISINS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Issuer has caused CUSIP numbers and ISINs to be printed on the Notes, and the Trustee may use CUSIP numbers and ISINs in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

(20) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THE NOTES AND THE GUARANTEES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

The Issuer will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

 

A1-8


ASSIGNMENT FORM

To assign this Note, fill in the form below:

 

(I) or (we) assign and transfer this Note to:     
  (Insert assignee’s legal name)

 

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

 

 

 

 

(Print or type assignee’s name, address and zip code)

 

and irrevocably appoint    

to transfer this Note on the books of the Issuer. The agent may substitute another to act for him.

Date: _____________________

 

Your Signature:    
(Sign exactly as your name appears on the face of this Note)

Signature Guarantee*: ______________________

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A1-9


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Issuer pursuant to Section 4.10 or 4.15 of the Indenture, check the appropriate box below:

☐ Section 4.10     ☐ Section 4.15

If you want to elect to have only part of the Note purchased by the Issuer pursuant to Section 4.10 or Section 4.15 of the Indenture, state the amount you elect to have purchased:

$ _____________

Date: ________________

 

Your Signature:

   

(Sign exactly as your name appears on the face of this Note)

Tax Identification No.:

   

Signature Guarantee*: ___________________

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A1-10


SCHEDULE OF EXCHANGES OF INTERESTS IN THE GLOBAL NOTE *

The initial outstanding principal amount of this Global Note is $ ________. The following exchanges of a part of this Global Note for an interest in another Global Note or for a Definitive Note, or exchanges of a part of another Global Note or Definitive Note for an interest in this Global Note, have been made:

 

Date of Exchange

 

Amount of

decrease in

Principal

Amount

of

this Global Note

 

Amount of

increase in

Principal

Amount

of

this Global Note

 

Principal Amount of this Global
Note following such decrease
(or increase)

 

Signature of authorized officer

of Trustee or Custodian

 

*

This schedule should be included only if the Note is issued in global form.

 

A1-11


EXHIBIT A-2

[Face of Note]

 

[Insert the Global Note Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Private Placement Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Regulation S Temporary Note Legend, if applicable pursuant to the provisions of the indenture]

 

A2-1


CUSIP      9

ISIN      10

8.375% Senior Secured Notes due 2031

 

No.       [Initially]11 $      

VENTURE GLOBAL LNG, INC.

promises to pay to [Cede & Co.]12 [     ] or registered assigns, the principal sum [of                     UNITED STATES DOLLARS] or [as set forth on the Schedule of Exchanges of Interests in the Global Note attached hereto]13 on June 1, 2031.

Interest Payment Dates:  June 1 and December 1

Record Dates:      May 15 and November 15

Additional provisions of this Note are set forth on the other side of this Note.

 

9 

92332YAB7 (Rule 144A); U9220NAB7 (Reg S).

10 

US92332YAB74 (Rule 144A); USU9220NAB74 (Reg S).

11 

Include only if the Note is issued in global form.

12 

Include only if the Note is issued in global form.

13 

Include only if the Note is issued in global form.

 

A2-2


IN WITNESS HEREOF, the Issuer has caused this instrument to be duly executed.

Dated:      

 

VENTURE GLOBAL LNG, INC.

By:    
 

Name:

 

Title:

 

This is one of the Notes referred to

in the within-mentioned Indenture:

The Bank of New York Mellon Trust Company, N.A.,

as Trustee

By:    
  Authorized Signatory

 

A2-3


[Back of Note]

8.375% Senior Secured Notes due 2031

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global LNG, Inc., a Delaware corporation (the “Issuer”), promises to pay or cause to be paid interest on the principal amount of this Note at 8.375% per annum from [May 26, 2023]14 until maturity. The Issuer will pay interest, if any, semi-annually in arrears on June 1 and December 1 of each year, beginning on [December 1, 2023]15, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). The Issuer will make each interest payment to the Holder of record of this Note on the immediately preceding June 1 and December 1 (whether or not a Business Day) (each, a “Record Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from [May 26, 2023].16 Interest will be computed on the basis of a 360-day year comprised of twelve 30-day months.

(2) METHOD OF PAYMENT. The Issuer will pay interest on the Notes (except defaulted interest), if any, to the Persons who are registered Holders at the close of business on the May 15 or November 15 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium, if any, and interest, if any, at the office or agency of the Paying Agent and Registrar within the City and State of New York, or, at the option of the Issuer, payment of interest, if any, may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that (a) all cash payments of principal, premium, if any, and interest with respect to Notes represented by Global Notes registered in the name of or held by DTC or its nominee will be made through the Paying Agent by wire transfer of immediately available funds to the accounts specified by the registered Holder or Holders thereof and (b) all cash payments of principal, premium, if any, and interest with respect to certificated Notes may, at the option of the Issuer, be made by wire transfer to a U.S. dollar account maintained by the payee with a bank in the United States of America if such Holder elects payment by wire transfer by giving written notice to the Trustee or the Paying Agent to such effect designating such account no later than 30 days immediately preceding the relevant due date for payment (or such other date as the Trustee may accept in its discretion). Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar.

 

14 

In the case of Notes issued on the Issue Date.

15 

In the case of Notes issued on the Issue Date.

16 

In the case of Notes issued on the Issue Date.

 

A2-4


The Issuer may change the Paying Agent or Registrar without prior notice to the Holders. The Issuer or any of its Subsidiaries may act as Paying Agent or Registrar.

(4) INDENTURE. The Issuer issued the Notes under an Indenture, dated as of May 26, 2023 (the “Indenture”), among the Issuer, the Trustee and the Collateral Agent. The terms of the Notes include those stated in the Indenture. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are unsecured obligations of the Issuer. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

(a) At any time prior to June 1, 2026, the Issuer may on any one or more occasions redeem up to 40% of the aggregate principal amount of all Notes issued under the Indenture, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 108.375% of the principal amount of the Notes redeemed, plus accrued and unpaid interest, if any, to the date of redemption with an amount not to exceed the amount of net cash proceeds from one or more Equity Offerings consummated after the Issue Date; provided that:

(i) at least 50% of the aggregate principal amount of Notes issued under the Indenture on the Issue Date (excluding Notes held by the Issuer and its Subsidiaries) remains outstanding immediately after the occurrence of such redemption (unless all such Notes are otherwise repurchased or redeemed pursuant to another provision described under Article 3 of the Indenture); and

(ii) the redemption occurs within 180 days of the date of the closing of such Equity Offerings.

(b) At any time prior to June 1, 2026, the Issuer may on any one or more occasions redeem all or a part of the Notes, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 100% of the principal amount of the Notes redeemed, plus the Applicable Redemption Premium as of, and accrued and unpaid interest, if any, to the date of redemption.

(c) On or after June 1, 2026, the Issuer may on any one or more occasions redeem all or a part of the Notes, upon not less than 10 nor more than 60 days’ notice, at the redemption prices (expressed as percentages of principal amount) set forth below, plus accrued and unpaid interest, if any, on the Notes redeemed, to the applicable date of redemption, if redeemed during the twelve-month period beginning on June 1 of the years indicated below:

 

Year

   Percentage  

2026

     104.188%  

2027

     102.094%  

2028 and thereafter

     100.000%  

 

A2-5


Unless the Issuer defaults in the payment of the redemption price, interest will cease to accrue on the Notes or portions thereof called for redemption on the applicable redemption date.

(6) MANDATORY REDEMPTION. The Issuer is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control Triggering Event, the Issuer will be required to make an offer (a “Change of Control Offer”) to each Holder to repurchase all or any part (equal to $2,000 or an integral multiple of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash (the “Change of Control Payment”) equal to 101% of the aggregate principal amount of Notes repurchased, plus accrued and unpaid interest, if any, on the Notes repurchased to, but not including, the date of purchase, subject to the rights of Holders of Notes on the relevant record date to receive interest due on the relevant Interest Payment Date. Within thirty days following any Change of Control Triggering Event, the Issuer will mail, or deliver electronically if the Notes are held at DTC, a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Issuer will be required to make a Collateral Asset Sale Offer or an Asset Sale Offer to the extent provided in Section 4.10 of the Indenture.

(8) NOTICE OF REDEMPTION. At least 10 days but not more than 60 days before a redemption date, the Issuer will mail or cause to be mailed, by first class mail (or, in the case of Global Notes, transmit with the procedures of the Depositary), a notice of redemption to each Holder (with a copy to the Trustee) whose Notes are to be redeemed at its registered address, except that redemption notices may be mailed or transmitted more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes or a satisfaction and discharge of the Indenture pursuant to Articles 8 or 11 thereof Notes and portions of Notes selected will be in amounts of $2,000 or whole multiples of $1,000 in excess thereof; except that if all of the Notes of a Holder are to be redeemed or purchased, the entire outstanding amount of Notes held by such Holder shall be redeemed or purchased.

Any such redemption may, at the Issuer’s discretion, be subject to one or more conditions precedent, including completion of any related Equity Offerings, Change of Control or other transaction. In addition, if such redemption is subject to the satisfaction of one or more conditions precedent, the related notice shall describe each such condition, and if applicable, shall state that, in the Issuer’s discretion, the date of redemption may be delayed until such time as any or all such conditions shall be satisfied or waived, or such redemption or purchase may not occur and such notice may be rescinded in the event that any or all such conditions shall not have been satisfied or waived by the date of redemption, or by the date of redemption as so delayed. In addition, the Issuer may provide in such notice that payment of the redemption price and performance of the Issuer’s obligations with respect to such redemption may be performed by another Person (it being understood that any such provision for payment by another Person will not relieve the Issuer and the Guarantors from their obligations with respect to such redemption).

 

A2-6


(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Issuer may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Issuer need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Issuer need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the next succeeding Interest Payment Date.

(10) PERSONS DEEMED OWNERS. The registered Holder may be treated as the owner of it for all purposes. Only registered Holders have rights under the Indenture.

(11) AMENDMENT, SUPPLEMENT AND WAIVER. Subject to certain exceptions, the Indenture, the Notes or the Guarantees may be amended or supplemented as provided in the Indenture.

(12) DEFAULTS AND REMEDIES. The Events of Default relating to the Notes are defined in Section 6.01 of the Indenture. If any Event of Default (other than an Event of Default of the type specified in clause (h) or (i) of Section 6.01 of the Indenture with respect to the Issuer) occurs and is continuing under the Indenture, the Trustee or the Holders of not less than 30% in aggregate principal amount of all of the then outstanding Notes may, by written notice to the Issuer and the Trustee, declare all of the Notes to be due and payable immediately. Upon any such declaration, the Notes shall become due and payable immediately. Notwithstanding the foregoing, in the case of an Event of Default arising under clause (h) or (i) of Section 6.01 of the Indenture with respect to the Issuer, all outstanding Notes will become due and payable immediately without further action or notice. Holders may not enforce the Indenture, the Notes, the Security Documents or the Guarantees except as provided in the Indenture. Subject to certain limitations, Holders of a majority in aggregate principal amount of all the Notes then outstanding may direct the Trustee in its exercise of any trust or power.

(13) TRUSTEE DEALINGS WITH ISSUER. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Issuer or its Affiliates, and may otherwise deal with the Issuer or its Affiliates, as if it were not the Trustee.

(14) GUARANTEES. The Issuer’s obligations under the Notes are fully and unconditionally guaranteed, jointly and severally, by the Guarantors, if any, to the extent set forth in Article 10 of the Indenture.

(15) SECURITY. The Notes and the related Guarantees, if any, will be secured by the Collateral on the terms and subject to the conditions set forth in the Indenture and the Security Documents. The Collateral Agent holds the Collateral in trust for the benefit of the Holders of the Notes, in each case pursuant to the Security Documents, the Collateral Agency Agreement and any Acceptable Intercreditor Agreement. Each Holder, by accepting this Note, consents and agrees to the terms of the Security Documents (including the provisions providing for the foreclosure and release of Collateral), the Collateral Agency Agreement and any Acceptable

 

A2-7


Intercreditor Agreement, each as may be in effect or may be amended from time to time in accordance with their terms and the Indenture, and authorizes and directs the Trustee, the Collateral Agent and any common collateral agent (if any) to enter into the Security Documents, the Collateral Agency Agreement and any Acceptable Intercreditor Agreement at any time after the Issue Date, if applicable, and to perform its obligations and exercise its rights thereunder in accordance therewith.

(16) NO RECOURSE AGAINST OTHERS. No director, officer, employee, incorporator or stockholder of the Issuer or any Guarantor, as such, will have any liability for any obligations of the Issuer or the Guarantors under the Notes, the Indenture, the Guarantees, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(17) AUTHENTICATION. This Note will not be entitled to any benefit under the Indenture or be valid or obligatory for any purposes until authenticated by the manual signature of the Trustee or an authenticating agent.

(18) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(19) CUSIP NUMBERS AND ISINS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Issuer has caused CUSIP numbers and ISINs to be printed on the Notes, and the Trustee may use CUSIP numbers and ISINs in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

(20) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THE NOTES AND THE GUARANTEES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

The Issuer will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

 

A2-8


ASSIGNMENT FORM

To assign this Note, fill in the form below:

 

(I) or (we) assign and transfer this Note to:     
   (Insert assignee’s legal name)

 

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

 

 

(Print or type assignee’s name, address and zip code)

 

and irrevocably appoint    

to transfer this Note on the books of the Issuer. The agent may substitute another to act for him.

Date:      

 

Your Signature:    
(Sign exactly as your name appears on the face of this Note)

 

Signature Guarantee*:    

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A2-9


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Issuer pursuant to Section 4.10 or 4.15 of the Indenture, check the appropriate box below:

☐ Section 4.10    ☐ Section 4.15

If you want to elect to have only part of the Note purchased by the Issuer pursuant to Section 4.10 or Section 4.15 of the Indenture, state the amount you elect to have purchased:

$     

Date:      

 

Your Signature:    
(Sign exactly as your name appears on the face of this Note)

 

Tax Identification No.:    

 

Signature Guarantee*:    

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A2-10


SCHEDULE OF EXCHANGES OF INTERESTS IN THE GLOBAL NOTE *

The initial outstanding principal amount of this Global Note is $    . The following exchanges of a part of this Global Note for an interest in another Global Note or for a Definitive Note, or exchanges of a part of another Global Note or Definitive Note for an interest in this Global Note, have been made:

 

Date of Exchange

 

Amount of decrease in

Principal Amount

of

this Global Note

 

Amount of increase in Principal

Amount

of

this Global Note

 

Principal Amount of this Global

Note following such decrease

(or increase)

 

Signature of authorized officer

of Trustee or Custodian

 

*

This schedule should be included only if the Note is issued in global form.

 

A2-11


EXHIBIT B

FORM OF CERTIFICATE OF TRANSFER (2028 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: [Chief Financial Officer and General Counsel]

The Bank of New York Mellon Trust Company, N.A

[•]

Attention: [•]

Re: 8.125% Senior Secured Notes due 2028

Reference is hereby made to the Indenture, dated as of May 26, 2023 (the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A, as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

             , (the “Transferor”) owns and proposes to transfer the Note[s] or interest in such Note[s] specified in Annex A hereto, in the principal amount of $     in such Note[s] or interests (the “Transfer”), to        (the “Transferee”), as further specified in Annex A hereto. In connection with the Transfer, the Transferor hereby certifies that:

[CHECK ALL THAT APPLY]

1. ☐ Check if Transferee will take delivery of a beneficial interest in the 144A Global Note or a Restricted Definitive Note pursuant to Rule 144A. The Transfer is being effected pursuant to and in accordance with Rule 144A under the Securities Act of 1933, as amended (the “Securities Act”), and, accordingly, the Transferor hereby further certifies that the beneficial interest or Definitive Note is being transferred to a Person that the Transferor reasonably believes is purchasing the beneficial interest or Definitive Note for its own account, or for one or more accounts with respect to which such Person exercises sole investment discretion, and such Person and each such account is a “qualified institutional buyer” within the meaning of Rule 144A in a transaction meeting the requirements of Rule 144A, and such Transfer is in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the 144A Global Note and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

 

B-1


2. ☐ Check if Transferee will take delivery of a beneficial interest in the Regulation S Temporary Global Note, the Regulation S Permanent Global Note or a Restricted Definitive Note pursuant to Regulation S. The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and, accordingly, the Transferor hereby further certifies that (i) the Transfer is not being made to a Person in the United States and (x) at the time the buy order was originated, the Transferee was outside the United States or such Transferor and any Person acting on its behalf reasonably believed and believes that the Transferee was outside the United States or (y) the transaction was executed in, on or through the facilities of a designated offshore securities market and neither such Transferor nor any Person acting on its behalf knows that the transaction was prearranged with a buyer in the United States, (ii) no directed selling efforts have been made in contravention of the requirements of Rule 903(b) or Rule 904(b) of Regulation S under the Securities Act, (iii) the transaction is not part of a plan or scheme to evade the registration requirements of the Securities Act and (iv) if the proposed transfer is being made prior to the expiration of the Restricted Period, the transfer is not being made to a U.S. Person or for the account or benefit of a U.S. Person (other than an Initial Purchaser). Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on Transfer enumerated in the Private Placement Legend printed on the Regulation S Permanent Global Note, the Regulation S Temporary Global Note, and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

3. ☐ Check and complete if Transferee will take delivery of a beneficial interest in the IAI Global Note or a Restricted Definitive Note pursuant to any provision of the Securities Act other than Rule 144A or Regulation S. The Transfer is being effected in compliance with the transfer restrictions applicable to beneficial interests in Restricted Global Notes and Restricted Definitive Notes and pursuant to and in accordance with the Securities Act and any applicable blue sky securities laws of any state of the United States, and accordingly the Transferor hereby further certifies that (check one):

(a) ☐ such Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act;

or

(b) ☐ such Transfer is being effected to the Issuer or a subsidiary thereof; or

(c) ☐ such Transfer is being effected pursuant to an effective registration statement under the Securities Act and in compliance with the prospectus delivery requirements of the Securities Act;

or

(d) ☐ such Transfer is being effected to an Institutional Accredited Investor and pursuant to an exemption from the registration requirements of the Securities Act other than Rule 144A, Rule 144, Rule 903 or Rule 904, and the Transferor hereby further certifies that it has not engaged in any general solicitation within the meaning of Regulation D under the Securities Act and the Transfer complies with the transfer restrictions applicable to beneficial interests in a Restricted Global Note or Restricted Definitive Notes and the requirements of the exemption claimed, which certification is supported by (1) a certificate executed by the Transferee in the form of Exhibit D to the Indenture and (2) if such Transfer is in respect of a principal amount of Notes

 

B-2


at the time of transfer of less than $250,000, an Opinion of Counsel provided by the Transferor or the Transferee (a copy of which the Transferor has attached to this certification), to the effect that such Transfer is in compliance with the Securities Act. Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the IAI Global Note and/or the Restricted Definitive Notes and in the Indenture and the Securities Act.

4. ☐ Check if Transferee will take delivery of a beneficial interest in an Unrestricted Global Note or of an Unrestricted Definitive Note.

(a) ☐ Check if Transfer is pursuant to Rule 144. (i) The Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

(b) ☐ Check if Transfer is Pursuant to Regulation S. (i) The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

(c) ☐ Check if Transfer is Pursuant to Other Exemption. (i) The Transfer is being effected pursuant to and in compliance with an exemption from the registration requirements of the Securities Act other than Rule 144, Rule 903 or Rule 904 and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any State of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will not be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes or Restricted Definitive Notes and in the Indenture.

 

B-3


This certificate and the statements contained herein are made for your benefit and the benefit of the Issuer.

 

 

[Insert Name of Transferor]

By:

   
 

Name:

 

Title:

Dated:       

 

B-4


ANNEX A TO CERTIFICATE OF TRANSFER

 

1.

The Transferor owns and proposes to transfer the following:

[CHECK ONE OF (a) OR (b)]

 

(a)

☐ a beneficial interest in the:

 

  (i)

☐ 144A Global Note (CUSIP     ), or

 

  (ii)

☐ Regulation S Global Note (CUSIP     ), or

 

  (iii)

☐ IAI Global Note (CUSIP     ); or

 

(b)

☐ a Restricted Definitive Note.

 

2.

After the Transfer the Transferee will hold:

[CHECK ONE]

 

(a)

☐ a beneficial interest in the:

 

  (i)

☐ 144A Global Note (CUSIP     ), or

 

  (ii)

☐ Regulation S Global Note (CUSIP     ), or

 

  (iii)

☐ IAI Global Note (CUSIP     ); or

 

  (iv)

☐ Unrestricted Global Note (CUSIP     ); or

 

(b)

☐ a Restricted Definitive Note; or

 

(c)

☐ an Unrestricted Definitive Note,

in accordance with the terms of the Indenture.

 

B-5


FORM OF CERTIFICATE OF TRANSFER (2031 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: [Chief Financial Officer and General Counsel]

The Bank of New York Mellon Trust Company, N.A

[•]

Attention: [•]

Re: 8.375% Senior Secured Notes due 2031

Reference is hereby made to the Indenture, dated as of May 26, 2023 (the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A, as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

     , (the “Transferor”) owns and proposes to transfer the Note[s] or interest in such Note[s] specified in Annex A hereto, in the principal amount of    $     in such Note[s] or interests (the “Transfer”), to     (the “Transferee”), as further specified in Annex A hereto. In connection with the Transfer, the Transferor hereby certifies that:

[CHECK ALL THAT APPLY]

1. ☐ Check if Transferee will take delivery of a beneficial interest in the 144A Global Note or a Restricted Definitive Note pursuant to Rule 144A. The Transfer is being effected pursuant to and in accordance with Rule 144A under the Securities Act of 1933, as amended (the “Securities Act”), and, accordingly, the Transferor hereby further certifies that the beneficial interest or Definitive Note is being transferred to a Person that the Transferor reasonably believes is purchasing the beneficial interest or Definitive Note for its own account, or for one or more accounts with respect to which such Person exercises sole investment discretion, and such Person and each such account is a “qualified institutional buyer” within the meaning of Rule 144A in a transaction meeting the requirements of Rule 144A, and such Transfer is in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the 144A Global Note and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

2. ☐ Check if Transferee will take delivery of a beneficial interest in the Regulation S Temporary Global Note, the Regulation S Permanent Global Note or a Restricted Definitive Note pursuant to Regulation S. The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and, accordingly, the Transferor hereby further certifies that (i) the Transfer is not being made to a Person in the United States and (x) at the time the buy order was originated, the Transferee was outside the United

 

B-6


States or such Transferor and any Person acting on its behalf reasonably believed and believes that the Transferee was outside the United States or (y) the transaction was executed in, on or through the facilities of a designated offshore securities market and neither such Transferor nor any Person acting on its behalf knows that the transaction was prearranged with a buyer in the United States, (ii) no directed selling efforts have been made in contravention of the requirements of Rule 903(b) or Rule 904(b) of Regulation S under the Securities Act, (iii) the transaction is not part of a plan or scheme to evade the registration requirements of the Securities Act and (iv) if the proposed transfer is being made prior to the expiration of the Restricted Period, the transfer is not being made to a U.S. Person or for the account or benefit of a U.S. Person (other than an Initial Purchaser). Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on Transfer enumerated in the Private Placement Legend printed on the Regulation S Permanent Global Note, the Regulation S Temporary Global Note, and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

3. ☐ Check and complete if Transferee will take delivery of a beneficial interest in the IAI Global Note or a Restricted Definitive Note pursuant to any provision of the Securities Act other than Rule 144A or Regulation S. The Transfer is being effected in compliance with the transfer restrictions applicable to beneficial interests in Restricted Global Notes and Restricted Definitive Notes and pursuant to and in accordance with the Securities Act and any applicable blue sky securities laws of any state of the United States, and accordingly the Transferor hereby further certifies that (check one):

(a) ☐ such Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act;

or

(b) ☐ such Transfer is being effected to the Issuer or a subsidiary thereof; or

(c) ☐ such Transfer is being effected pursuant to an effective registration statement under the Securities Act and in compliance with the prospectus delivery requirements of the Securities Act;

or

(d) ☐ such Transfer is being effected to an Institutional Accredited Investor and pursuant to an exemption from the registration requirements of the Securities Act other than Rule 144A, Rule 144, Rule 903 or Rule 904, and the Transferor hereby further certifies that it has not engaged in any general solicitation within the meaning of Regulation D under the Securities Act and the Transfer complies with the transfer restrictions applicable to beneficial interests in a Restricted Global Note or Restricted Definitive Notes and the requirements of the exemption claimed, which certification is supported by (1) a certificate executed by the Transferee in the form of Exhibit D to the Indenture and (2) if such Transfer is in respect of a principal amount of Notes at the time of transfer of less than $250,000, an Opinion of Counsel provided by the Transferor or the Transferee (a copy of which the Transferor has attached to this certification), to the effect that such Transfer is in compliance with the Securities Act. Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the IAI Global Note and/or the Restricted Definitive Notes and in the Indenture and the Securities Act.

 

B-7


4. ☐ Check if Transferee will take delivery of a beneficial interest in an Unrestricted Global Note or of an Unrestricted Definitive Note.

(a) ☐ Check if Transfer is pursuant to Rule 144. (i) The Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

(b) ☐ Check if Transfer is Pursuant to Regulation S. (i) The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

(c) ☐ Check if Transfer is Pursuant to Other Exemption. (i) The Transfer is being effected pursuant to and in compliance with an exemption from the registration requirements of the Securities Act other than Rule 144, Rule 903 or Rule 904 and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any State of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will not be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes or Restricted Definitive Notes and in the Indenture.

 

B-8


This certificate and the statements contained herein are made for your benefit and the benefit of the Issuer.

 

 
[Insert Name of Transferor]
By:    
  Name:
  Title:

Dated:         

 

B-9


ANNEX A TO CERTIFICATE OF TRANSFER

 

1.

The Transferor owns and proposes to transfer the following:

[CHECK ONE OF (a) OR (b)]

 

(a)

☐ a beneficial interest in the:

 

  (i)

☐ 144A Global Note (CUSIP     ), or

 

  (ii)

☐ Regulation S Global Note (CUSIP     ), or

 

  (iii)

☐ IAI Global Note (CUSIP     ); or

 

(b)

☐ a Restricted Definitive Note.

 

2.

After the Transfer the Transferee will hold:

[CHECK ONE]

 

(a)

☐ a beneficial interest in the:

 

  (i)

☐ 144A Global Note (CUSIP     ), or

 

  (ii)

☐ Regulation S Global Note (CUSIP     ), or

 

  (iii)

☐ IAI Global Note (CUSIP     ); or

 

  (iv)

☐ Unrestricted Global Note (CUSIP     ); or

 

(b)

☐ a Restricted Definitive Note; or

 

(c)

☐ an Unrestricted Definitive Note,

in accordance with the terms of the Indenture.

 

B-10


EXHIBIT C

FORM OF CERTIFICATE OF EXCHANGE (2028 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: [Chief Financial Officer and General Counsel]

The Bank of New York Mellon Trust Company, N.A 60 [•]

Attention: [•]

Re: 8.125% Senior Secured Notes due 2028

(CUSIP [ ])

Reference is hereby made to the Indenture, dated as of May 26, 2023 (the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A, as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

      , (the “Owner”) owns and proposes to exchange the Note[s] or interest in such Note[s] specified herein, in the principal amount of $    in such Note[s] or interests (the “Exchange”). In connection with the Exchange, the Owner hereby certifies that:

1. Exchange of Restricted Definitive Notes or Beneficial Interests in a Restricted Global Note for Unrestricted Definitive Notes or Beneficial Interests in an Unrestricted Global Note

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to beneficial interest in an Unrestricted Global Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a beneficial interest in an Unrestricted Global Note in an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Global Notes and pursuant to and in accordance with the Securities Act of 1933, as amended (the “Securities Act”), (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest in an Unrestricted Global Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(b) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Unrestricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

 

C-1


(c) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in an Unrestricted Global Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for a beneficial interest in an Unrestricted Global Note, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(d) ☐ Check if Exchange is from Restricted Definitive Note to Unrestricted Definitive Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Unrestricted Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Unrestricted Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

2. Exchange of Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes for Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Restricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a Restricted Definitive Note with an equal principal amount, the Owner hereby certifies that the Restricted Definitive Note is being acquired for the Owner’s own account without transfer. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the Restricted Definitive Note issued will continue to be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Definitive Note and in the Indenture and the Securities Act.

(b) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in a Restricted Global Note. In connection with the Exchange of the Owner’s Restricted Definitive Note for a beneficial interest in the [CHECK ONE] ☐ 144A Global Note, ☐ Regulation S Global Note, ☐ IAI Global Note with an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer and (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, and in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the beneficial interest issued will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the relevant Restricted Global Note and in the Indenture and the Securities Act.

 

C-2


This certificate and the statements contained herein are made for your benefit and the benefit of the Issuer.

 

 
[Insert Name of Transferor]
By:    
  Name:
  Title:

Dated:       

 

C-3


FORM OF CERTIFICATE OF EXCHANGE (2031 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: [Chief Financial Officer and General Counsel]

The Bank of New York Mellon Trust Company, N.A 60 [•]

Attention: [•]

Re: 8.375% Senior Secured Notes due 2031

(CUSIP [ ])

Reference is hereby made to the Indenture, dated as of May 26, 2023 (the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A, as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

      , (the “Owner”) owns and proposes to exchange the Note[s] or interest in such Note[s] specified herein, in the principal amount of $    in such Note[s] or interests (the “Exchange”). In connection with the Exchange, the Owner hereby certifies that:

1. Exchange of Restricted Definitive Notes or Beneficial Interests in a Restricted Global Note for Unrestricted Definitive Notes or Beneficial Interests in an Unrestricted Global Note

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to beneficial interest in an Unrestricted Global Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a beneficial interest in an Unrestricted Global Note in an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Global Notes and pursuant to and in accordance with the Securities Act of 1933, as amended (the “Securities Act”), (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest in an Unrestricted Global Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(b) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Unrestricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

 

C-4


(c) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in an Unrestricted Global Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for a beneficial interest in an Unrestricted Global Note, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(d) ☐ Check if Exchange is from Restricted Definitive Note to Unrestricted Definitive Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Unrestricted Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Unrestricted Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

2. Exchange of Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes for Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Restricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a Restricted Definitive Note with an equal principal amount, the Owner hereby certifies that the Restricted Definitive Note is being acquired for the Owner’s own account without transfer. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the Restricted Definitive Note issued will continue to be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Definitive Note and in the Indenture and the Securities Act.

(b) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in a Restricted Global Note. In connection with the Exchange of the Owner’s Restricted Definitive Note for a beneficial interest in the [CHECK ONE] ☐ 144A Global Note, ☐ Regulation S Global Note, ☐ IAI Global Note with an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer and (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, and in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the beneficial interest issued will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the relevant Restricted Global Note and in the Indenture and the Securities Act.

 

C-5


This certificate and the statements contained herein are made for your benefit and the benefit of the Issuer.

 

 
[Insert Name of Transferor]
By:    
  Name:
  Title:

Dated:       

 

C-6


EXHIBIT D

FORM OF CERTIFICATE FROM

ACQUIRING INSTITUTIONAL ACCREDITED INVESTOR (2028 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: [Chief Financial Officer and General Counsel]

The Bank of New York Mellon Trust Company, N.A

[•]

Attention: [•]

Re: 8.125% Senior Secured Notes due 2028

Reference is hereby made to the Indenture, dated as of May 26, 2023 (the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A, as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

In connection with our proposed purchase of $      aggregate  principal amount of:

(a) ☐ a beneficial interest in a Global Note, or

(b) ☐ a Definitive Note, we confirm that:

1. We understand that any subsequent transfer of the Notes or any interest therein is subject to certain restrictions and conditions set forth in the Indenture and the undersigned agrees to be bound by, and not to resell, pledge or otherwise transfer the Notes or any interest therein except in compliance with, such restrictions and conditions and the Securities Act of 1933, as amended (the “Securities Act”).

2. We understand that the offer and sale of the Notes have not been registered under the Securities Act, and that the Notes and any interest therein may not be offered or sold except as permitted in the following sentence. We agree, on our own behalf and on behalf of any accounts for which we are acting as hereinafter stated, that if we should sell the Notes or any interest therein, we will do so only (A) to the Issuer or any subsidiary thereof, (B) in accordance with Rule 144A under the Securities Act to a “qualified institutional buyer” (as defined therein), (C) to an institutional “accredited investor” (as defined below) that, prior to such transfer, furnishes (or has furnished on its behalf by a U.S. broker-dealer) to you and to the Issuer a signed letter substantially in the form of this letter and, if such transfer is in respect of a principal amount of Notes, at the time of transfer of less than $250,000, an Opinion of Counsel in form reasonably acceptable to the Issuer to the effect that such transfer is in compliance with the Securities Act, (D) outside the

 

D-1


United States in accordance with Rule 904 of Regulation S under the Securities Act, (E) pursuant to the provisions of Rule 144 under the Securities Act or (F) pursuant to an effective registration statement under the Securities Act, and we further agree to provide to any Person purchasing the Definitive Note or beneficial interest in a Global Note from us in a transaction meeting the requirements of clauses (A) through (E) of this paragraph a notice advising such purchaser that resales thereof are restricted as stated herein.

3. We understand that, on any proposed resale of the Notes or beneficial interest therein, we will be required to furnish to you and the Issuer such certifications, legal opinions and other information as you and the Issuer may reasonably require to confirm that the proposed sale complies with the foregoing restrictions. We further understand that the Notes purchased by us will bear a legend to the foregoing effect.

4. We are an institutional “accredited investor” (as defined in Rule 501(a)(1), (2), (3) or (7) of Regulation D under the Securities Act) and have such knowledge and experience in financial and business matters as to be capable of evaluating the merits and risks of our investment in the Notes, and we and any accounts for which we are acting are each able to bear the economic risk of our or its investment.

5. We are acquiring the Notes or beneficial interest therein purchased by us for our own account or for one or more accounts (each of which is an institutional “accredited investor”) as to each of which we exercise sole investment discretion.

You and the Issuer are entitled to rely upon this letter and are irrevocably authorized to produce this letter or a copy hereof to any interested party in any administrative or legal proceedings or official inquiry with respect to the matters covered hereby.

 

 
[Insert Name of Accredited Investor]
By:    
  Name:
  Title:

Dated:       

 

D-2


FORM OF CERTIFICATE FROM

ACQUIRING INSTITUTIONAL ACCREDITED INVESTOR (2031 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

The Bank of New York Mellon Trust Company, N.A

[•]

Attention: [•]

Re: 8.375% Senior Secured Notes due 2031

Reference is hereby made to the Indenture, dated as of May 26, 2023 (the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A, as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

In connection with our proposed purchase of $      aggregate  principal amount of:

(a) ☐ a beneficial interest in a Global Note, or

(b) ☐ a Definitive Note,

we confirm that:

1. We understand that any subsequent transfer of the Notes or any interest therein is subject to certain restrictions and conditions set forth in the Indenture and the undersigned agrees to be bound by, and not to resell, pledge or otherwise transfer the Notes or any interest therein except in compliance with, such restrictions and conditions and the Securities Act of 1933, as amended (the “Securities Act”).

2. We understand that the offer and sale of the Notes have not been registered under the Securities Act, and that the Notes and any interest therein may not be offered or sold except as permitted in the following sentence. We agree, on our own behalf and on behalf of any accounts for which we are acting as hereinafter stated, that if we should sell the Notes or any interest therein, we will do so only (A) to the Issuer or any subsidiary thereof, (B) in accordance with Rule 144A under the Securities Act to a “qualified institutional buyer” (as defined therein), (C) to an institutional “accredited investor” (as defined below) that, prior to such transfer, furnishes (or has furnished on its behalf by a U.S. broker-dealer) to you and to the Issuer a signed letter substantially in the form of this letter and, if such transfer is in respect of a principal amount of Notes, at the time of transfer of less than $250,000, an Opinion of Counsel in form reasonably acceptable to the Issuer to the effect that such transfer is in compliance with the Securities Act, (D) outside the United States in accordance with Rule 904 of Regulation S under the Securities Act, (E) pursuant to the provisions of Rule 144 under the Securities Act or (F) pursuant to an effective registration statement under the Securities Act, and we further agree to provide to any Person purchasing the Definitive Note or beneficial interest in a Global Note from us in a transaction meeting the requirements of clauses (A) through (E) of this paragraph a notice advising such purchaser that resales thereof are restricted as stated herein.

 

D-3


3. We understand that, on any proposed resale of the Notes or beneficial interest therein, we will be required to furnish to you and the Issuer such certifications, legal opinions and other information as you and the Issuer may reasonably require to confirm that the proposed sale complies with the foregoing restrictions. We further understand that the Notes purchased by us will bear a legend to the foregoing effect.

4. We are an institutional “accredited investor” (as defined in Rule 501(a)(1), (2), (3) or (7) of Regulation D under the Securities Act) and have such knowledge and experience in financial and business matters as to be capable of evaluating the merits and risks of our investment in the Notes, and we and any accounts for which we are acting are each able to bear the economic risk of our or its investment.

5. We are acquiring the Notes or beneficial interest therein purchased by us for our own account or for one or more accounts (each of which is an institutional “accredited investor”) as to each of which we exercise sole investment discretion.

You and the Issuer are entitled to rely upon this letter and are irrevocably authorized to produce this letter or a copy hereof to any interested party in any administrative or legal proceedings or official inquiry with respect to the matters covered hereby.

 

 
[Insert Name of Accredited Investor]
By:    
  Name:
  Title:

Dated:       

 

D-4


EXHIBIT E

FORM OF SUPPLEMENTAL INDENTURE

TO BE DELIVERED BY SUBSEQUENT GUARANTORS

[Omitted]


EXHIBIT F to the Indenture

[FORM OF] FIRST LIEN INTERCREDITOR AGREEMENT

[Omitted]


EXHIBIT G to the Indenture

[FORM OF] JUNIOR LIEN INTERCREDITOR AGREEMENT

[Omitted]

Exhibit 10.92

FIRST SUPPLEMENTAL INDENTURE

FIRST SUPPLEMENTAL INDENTURE (this “Supplemental Indenture”), dated as of September 25, 2023 between Venture Global LNG, Inc., a Delaware corporation (the “Issuer”), and The Bank of New York Mellon Trust Company, N.A, as Trustee (in such capacity, the “Trustee”) and Collateral Agent (in such capacity, the “Collateral Agent”) under the Indenture referred to below.

W I T N E S S E T H

WHEREAS, the Issuer has heretofore executed and delivered to the Trustee and the Collateral Agent an indenture (the “Indenture”), dated as of May 26, 2023, providing for the issuance of 8.125% Senior Secured Notes due 2028 and 8.375% Senior Secured Notes due 2031 (the “Notes”);

WHEREAS, Section 9.01(i) of the Indenture provides that without the consent of any Holder, the Issuer, the Trustee and the Collateral Agent may amend or supplement the Indenture to conform the text of the Indenture to any provision of the “Description of Notes” section of the Offering Memorandum as set forth in an Officer’s Certificate to that effect;

WHEREAS the Issuer has on the date of this Supplemental Indenture delivered to each of the Trustee and the Collateral Agent (i) an Officer’s Certificate and (ii) an Opinion of Counsel, each relating to the amendments to the Indenture proposed to be made pursuant to this Supplemental Indenture; and

WHEREAS, pursuant to Section 9.01(i) and Section 9.05 of the Indenture, the Trustee and the Collateral Agent are authorized to execute and deliver this Supplemental Indenture.

NOW, THEREFORE, in consideration of the foregoing and for other good and valuable consideration, the receipt of which is hereby acknowledged, the Issuer, the Trustee and the Collateral Agent mutually covenant and agree for the equal and ratable benefit of the Holders as follows:

1. CAPITALIZED TERMS. Capitalized terms used herein without definition shall have the meanings assigned to them in the Indenture.

2. LIMITATION ON RESTRICTED PAYMENTS AMENDMENT. Effective as of the date hereof, Section 4.07(b)(14) of the Indenture shall be amended to add the text marked with an underscore and delete the text marked with a strikethrough below in order to conform such section to clause 2(n) of the “Description of Notes—Limitation on Restricted Payments” section of the Offering Memorandum:

(14) other Restricted Payments, so long as the Holdco Debt Ratio is no greater than 0.800.95 to 1.0 determined on a pro forma basis for the applicable Test Period; provided, however, that at the time of, and after giving effect to, any Restricted Payment permitted under this clause (14), no Event of Default shall have occurred and be continuing or would otherwise occur as a consequence thereof;


3. NO RECOURSE AGAINST OTHERS. No director, officer, employee, incorporator or stockholder of the Issuer, as such, will have any liability for any obligations of the Issuer under the Notes, this Supplemental Indenture, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

4. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THIS SUPPLEMENTAL INDENTURE AND THE NOTES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5- 1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

5. EXECUTION; COUNTERPART ORIGINALS. The parties may manually or electronically sign any number of copies of this Supplemental Indenture. Each signed copy will be an original, but all of them together represent the same agreement. The exchange of copies of this Supplemental Indenture and of signature pages by facsimile or electronic format (i.e., “pdf” or “tif”) transmission shall constitute effective execution and delivery of this Supplemental Indenture as to the parties hereto and may be used in lieu of the original Supplemental Indenture for all purposes. Signatures of the parties hereto transmitted by facsimile or electronic format (i.e., “pdf” or “tif”) shall be deemed to be their original signatures for all purposes. Delivery of an executed Supplemental Indenture by one party to any other party may be made by facsimile, electronic mail (including any electronic signature complying with the New York Electronic Signatures and Records Act (N.Y. State Tech. §§ 301-309), as amended from time to time, or other applicable law), including DocuSign, or other transmission method, and the parties hereto agree that any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

6. EFFECT OF THIS SUPPLEMENTAL INDENTURE. This Supplemental Indenture is an amendment supplemental to the Indenture, and the Indenture and this Supplemental Indenture will henceforth be read together. Except as expressly supplemented and amended by this Supplemental Indenture, the Indenture shall continue in full force and effect in accordance with the provisions thereof, and the Indenture (as supplemented and amended by this Supplemental Indenture) is in all respects hereby ratified and confirmed. This Supplemental Indenture and all its provisions shall be deemed a part of the Indenture in the manner and to the extent herein and therein provided and all of the rights, powers, protections and indemnities of each of the Trustee and the Collateral Agent under the Indenture shall apply to this Supplemental Indenture. To the extent of any inconsistency between the terms of the Indenture and this Supplemental Indenture, the terms of this Supplemental Indenture will control. This Supplemental Indenture shall constitute an indenture supplemental to the Indenture and shall be construed in connection with and form a part of the Indenture for all purposes, and every Holder of the Notes heretofore or hereafter authenticated and delivered shall be bound hereby.

7. EFFECT OF HEADINGS. The Section headings herein are for convenience only and shall not affect the construction hereof.


8. THE TRUSTEE AND THE COLLATERAL AGENT. Neither the Trustee nor the Collateral Agent shall be responsible in any manner whatsoever for or in respect of the validity or sufficiency of this Supplemental Indenture or for or in respect of the recitals contained herein, all of which recitals are made solely by the Issuer. Additionally, neither the Trustee nor the Collateral Agent makes any representation as to the validity or sufficiency of this Supplemental Indenture. For the avoidance of doubt, neither the Trustee nor the Collateral Agent, by executing this Supplemental Indenture in accordance with the terms of the Indenture, agrees to undertake additional actions nor does it consent to any transaction beyond what is expressly set forth in this Supplemental Indenture, and each of the Trustee and the Collateral Agent reserves all rights and remedies under the Indenture.

9. PROVISIONS BINDING ON SUCCESSORS. All of the covenants, stipulations, promises and agreements made in this Supplemental Indenture by each of the parties hereto shall bind its successors and assigns whether so expressed or not.


IN WITNESS WHEREOF, the parties hereto have caused this Supplemental Indenture to be duly executed and attested, all as of the date first above written.

Dated: September 25, 2023

 

VENTURE GLOBAL LNG, INC.

By:

 

/s/ Jonathan W. Thayer

Name:

 

Jonathan W. Thayer

Title:

 

Chief Financial Officer

 

[Signature Page to First Supplemental Indenture]


THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee and Collateral Agent
By:   /s/ April Bradley
Name:   April Bradley
Title:   Vice President

 

[Signature Page to First Supplemental Indenture]

Exhibit 10.93

SECOND SUPPLEMENTAL INDENTURE

SECOND SUPPLEMENTAL INDENTURE (this “Supplemental Indenture”), dated as of September 28, 2023, among Venture Global Commodities, LLC, a Delaware limited liability company (the “Guaranteeing Subsidiary”), a subsidiary of Venture Global LNG, Inc. (or its permitted successor), a Delaware corporation (the “Issuer”), the Issuer and The Bank of New York Mellon Trust Company, N.A, as Trustee (in such capacity, the “Trustee”) and Collateral Agent (in such capacity, the “Collateral Agent”) under the Indenture referred to below.

W I T N E S S E T H

WHEREAS, the Issuer has heretofore executed and delivered to the Trustee and the Collateral Agent an indenture (as supplemented and amended prior to the date heorof, the “Indenture”), dated as of May 26, 2023, providing for the issuance of 8.125% Senior Secured Notes due 2028 and 8.375% Senior Secured Notes due 2031 (the “Notes”);

WHEREAS, the Indenture provides that under certain circumstances the Guaranteeing Subsidiary shall execute and deliver to the Trustee a supplemental indenture pursuant to which the Guaranteeing Subsidiary shall unconditionally guarantee all of the Issuer’s Obligations under the Notes and the Indenture on the terms and conditions set forth herein and in Article 10 of the Indenture (the “Guarantee”); and

WHEREAS, pursuant to Section 9.01(g) of the Indenture, the Trustee and the Collateral Agent are authorized to execute and deliver this Supplemental Indenture.

NOW, THEREFORE, in consideration of the foregoing and for other good and valuable consideration, the receipt of which is hereby acknowledged, the Guaranteeing Subsidiary, the Trustee and the Collateral Agent mutually covenant and agree for the equal and ratable benefit of the Holders as follows:

1. CAPITALIZED TERMS. Capitalized terms used herein without definition shall have the meanings assigned to them in the Indenture.

2. AGREEMENT TO GUARANTEE. The Guaranteeing Subsidiary hereby agrees to provide an unconditional Guarantee on the terms and subject to the conditions set forth in the Guarantee and in the Indenture including but not limited to Article 10 thereof

3. NO RECOURSE AGAINST OTHERS. No director, officer, employee, incorporator or stockholder of the Issuer or any Guarantor, as such, will have any liability for any obligations of the Issuer or the Guarantors under the Notes, this Supplemental Indenture, the Guarantees, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.


4. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THIS SUPPLEMENTAL INDENTURE, THE NOTES AND THE GUARANTEES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

5. EXECUTION; COUNTERPART ORIGINALS. The parties may manually or electronically sign any number of copies of this Supplemental Indenture. Each signed copy will be an original, but all of them together represent the same agreement. The exchange of copies of this Supplemental Indenture and of signature pages by facsimile or electronic format (i.e., “pdf” or “tif”) transmission shall constitute effective execution and delivery of this Supplemental Indenture as to the parties hereto and may be used in lieu of the original Supplemental Indenture for all purposes. Signatures of the parties hereto transmitted by facsimile or electronic format (i.e., “pdf” or “tif”) shall be deemed to be their original signatures for all purposes. Delivery of an executed Supplemental Indenture by one party to any other party may be made by facsimile, electronic mail (including any electronic signature complying with the New York Electronic Signatures and Records Act (N.Y. State Tech. §§ 301-309), as amended from time to time, or other applicable law), including DocuSign, or other transmission method, and the parties hereto agree that any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

6. EFFECT OF THIS SUPPLEMENTAL INDENTURE. This Supplemental Indenture is an amendment supplemental to the Indenture, and the Indenture and this Supplemental Indenture will henceforth be read together. Except as expressly supplemented and amended by this Supplemental Indenture, the Indenture shall continue in full force and effect in accordance with the provisions thereof, and the Indenture (as supplemented and amended by this Supplemental Indenture) is in all respects hereby ratified and confirmed. This Supplemental Indenture and all its provisions shall be deemed a part of the Indenture in the manner and to the extent herein and therein provided.

7. EFFECT OF HEADINGS. The Section headings herein are for convenience only and shall not affect the construction hereof.

8. THE TRUSTEE AND THE COLLATERAL AGENT. Neither the Trustee nor the Collateral Agent shall be responsible in any manner whatsoever for or in respect of the validity or sufficiency of this Supplemental Indenture or for or in respect of the recitals contained herein, all of which recitals are made solely by the Guaranteeing Subsidiary and the Issuer.


IN WITNESS WHEREOF, the parties hereto have caused this Supplemental Indenture to be duly executed and attested, all as of the date first above written.

Dated: September 28, 2023

 

VENTURE GLOBAL COMMODITIES, LLC
By:   /s/ Keith Larson
Name:   Keith Larson
Title:   General Counsel
VENTURE GLOBAL LNG, INC.
By:   /s/ Keith Larson
Name:   Keith Larson
Title:   General Counsel

[Signature Page to Supplemental Indenture (VGC Guarantee)]


THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee and Collateral Agent
By:   /s/ Ann M. Dolezal
Name:   Ann M. Dolezal
Title:   Vice President

[Signature Page to Supplemental Indenture (VGC Guarantee)]

Exhibit 10.94

THIRD SUPPLEMENTAL INDENTURE

THIRD SUPPLEMENTAL INDENTURE (this “Supplemental Indenture”), dated as of October 24, 2023, among Venture Global Commodities, LLC, a Delaware limited liability company (the “Guarantor”), a subsidiary of Venture Global LNG, Inc. (or its permitted successor), a Delaware corporation (the “Issuer”), the Issuer and The Bank of New York Mellon Trust Company, N.A, as Trustee (in such capacity, the “Trustee”) and Collateral Agent (in such capacity, the “Collateral Agent”) under the Indenture referred to below.

W I T N E S S E T H

WHEREAS, the Issuer has heretofore executed and delivered to the Trustee and the Collateral Agent an indenture (as supplemented and amended prior to the date hereof, the “Indenture”), dated as of May 26, 2023, providing for the issuance of 8.125% Senior Secured Notes due 2028 and 8.375% Senior Secured Notes due 2031 (the “Notes”);

WHEREAS, the Issuer and the Guarantor have heretofore executed and delivered to the Trustee that certain Second Supplemental Indenture, dated as of September 28, 2023, providing for the unconditional guarantee by the Guarantor of all of the Issuer’s Obligations under the Notes and the Indenture on the terms and conditions set forth therein and in Article 10 of the Indenture (the “Guarantee”);

WHEREAS, the Issuer taken such steps as to cause the repayment in full of that certain Credit and Guaranty Agreement originally dated August 30, 2021, as amended pursuant to that certain Augmenting Lender Supplement and First Amendment to Credit and Guaranty Agreement dated as of October 29, 2021, that certain Increasing Lender Supplement and Second Amendment to Credit and Guaranty Agreement dated as of June 17, 2022, that certain Increasing Lender Supplement and Third Amendment to Credit and Guaranty Agreement dated as of September 18, 2023 and that certain Consent and Fourth Amendment to Credit and Guaranty Agreement, dated as of September 28, 2023, by and among the Venture Global Partners, LLC, Venture Global Holdings, Inc. (as successor by way of merger to VGP), the Guarantor, the other guarantors from time to time party thereto, the lenders party thereto and JPMorgan Chase Bank, N.A., as successor to Morgan Stanley Senior Funding, Inc., as Administrative Agent (the “Prepayment”);

WHEREAS, as a result of the Prepayment, VG Commodities ceased to be an obligor to indebtedness in excess of the greater of (i) $250.0 million and (ii) 7.5% of Distributable Cash (as defined under the Existing Notes Indenture) for the applicable test period (as certified by the Issuer in an Officer’s Certificate delivered to the Trustee on the date hereof) and, pursuant to Sections 9.01(l) and 10.04(c) of the Existing Notes Indenture, the Guarantee of the Guarantor shall be released and discharged automatically and unconditionally; and

WHEREAS, pursuant to Section 9.01(l) of the Indenture, and the delivery of an Officer’s Certificate and an Opinion of Counsel to the Trustee and the Collateral Agent pursuant to Sections 7.02(b), 9.05 and 10.04(c) of the Indenture, the Trustee and the Collateral Agent are authorized to execute and deliver this Supplemental Indenture.


NOW, THEREFORE, in consideration of the foregoing and for other good and valuable consideration, the receipt of which is hereby acknowledged, the Guarantor, the Trustee and the Collateral Agent mutually covenant and agree for the equal and ratable benefit of the Holders as follows:

1. CAPITALIZED TERMS. Capitalized terms used herein without definition shall have the meanings assigned to them in the Indenture.

2. ACKNOWLEDGEMENT OF RELEASE OF GUARANTEE. The Trustee and Collateral Agent, subject to the conditions set forth in the Guarantee and in the Indenture including but not limited to Article 10 thereof, hereby acknowledges as evidenced by this Supplemental Indenture that the Guarantor has been released from its Guarantee.

3. NO RECOURSE AGAINST OTHERS. No director, officer, employee, incorporator or stockholder of the Issuer or any Guarantor, as such, will have any liability for any obligations of the Issuer or the Guarantors under the Notes, this Supplemental Indenture, the Guarantees, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

4. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THIS SUPPLEMENTAL INDENTURE, THE NOTES AND THE GUARANTEES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

5. EXECUTION; COUNTERPART ORIGINALS. The parties may manually or electronically sign any number of copies of this Supplemental Indenture. Each signed copy will be an original, but all of them together represent the same agreement. The exchange of copies of this Supplemental Indenture and of signature pages by facsimile or electronic format (i.e., “pdf” or “tif”) transmission shall constitute effective execution and delivery of this Supplemental Indenture as to the parties hereto and may be used in lieu of the original Supplemental Indenture for all purposes. Signatures of the parties hereto transmitted by facsimile or electronic format (i.e., “pdf” or “tif”) shall be deemed to be their original signatures for all purposes. Delivery of an executed Supplemental Indenture by one party to any other party may be made by facsimile, electronic mail (including any electronic signature complying with the New York Electronic Signatures and Records Act (N.Y. State Tech. §§ 301-309), as amended from time to time, or other applicable law), including DocuSign, or other transmission method, and the parties hereto agree that any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

6. EFFECT OF THIS SUPPLEMENTAL INDENTURE. This Supplemental Indenture is an amendment supplemental to the Indenture, and the Indenture and this Supplemental Indenture will henceforth be read together. Except as expressly supplemented and amended by this Supplemental Indenture, the Indenture shall continue in full force and effect in accordance with the provisions thereof, and the Indenture (as supplemented and amended by this Supplemental Indenture) is in all respects hereby ratified and confirmed. This Supplemental Indenture and all its provisions shall be deemed a part of the Indenture in the manner and to the extent herein and therein provided.


7. EFFECT OF HEADINGS. The Section headings herein are for convenience only and shall not affect the construction hereof.

8. THE TRUSTEE AND THE COLLATERAL AGENT. The Trustee and the Collateral Agent enter into this Supplemental Indenture at the request of the Issuer in reliance on the Officer’s Certificate and Opinions of Counsel delivered to them on the date hereof. In entering into this Supplemental Indenture, the Trustee and the Collateral Agent shall be entitled to the benefit of every provision of the Indenture (including, for the avoidance of doubt, Section 7.06 of the Indenture which is hereby expressly confirmed by the Issuer for the benefit of the Trustee) and the Notes relating to the conduct or affecting the liability or affording protection to the Trustee and the Collateral Agent, whether or not elsewhere herein so provided. Neither the Trustee nor the Collateral Agent shall be responsible in any manner whatsoever for or in respect of the validity or sufficiency of this Supplemental Indenture or for or in respect of the recitals contained herein, all of which recitals are made solely by the Guarantor and the Issuer.


IN WITNESS WHEREOF, the parties hereto have caused this Supplemental Indenture to be duly executed and attested, all as of the date first above written.

Dated: October 24, 2023

 

VENTURE GLOBAL COMMODITIES, LLC
By:   /s/ Keith Larson
Name:   Keith Larson
Title:   Authorized Officer
VENTURE GLOBAL LNG, INC.
By:   /s/ Jonathan W. Thayer
Name:   Jonathan W. Thayer
Title:   Chief Financial Officer
THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee and Collateral Agent
By:   /s/ Michele R. Shrum
Name:   Michele R. Shrum
Title:   Vice President

Exhibit 10.95

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

 

 

VENTURE GLOBAL LNG, INC.

AND EACH OF THE GUARANTORS PARTY HERETO FROM TIME TO TIME

9.500% SENIOR SECURED NOTES DUE 2029

9.875% SENIOR SECURED NOTES DUE 2032

 

 

INDENTURE

Dated as of October 24, 2023

 

 

 

 

The Bank of New York Mellon Trust Company, N.A.,

as Trustee and Collateral Agent

 

 

 

 


TABLE OF CONTENTS

 

ARTICLE 1

 

DEFINITIONS AND INCORPORATION BY REFERENCE

  

Section 1.01

  Definitions      1  

Section 1.02

  Other Definitions      49  

Section 1.03

  Rules of Construction      50  

Section 1.04

  Limited Condition Transactions      52  

Section 1.05

  Certain Compliance Calculations      53  

Section 1.06

  Acts of Holders      53  

Section 1.07

  Timing of Payment      55  

Section 1.08

  Role of the Collateral Agent      55  

ARTICLE 2

 

THE NOTES

  

Section 2.01

  Form and Dating      55  

Section 2.02

  Execution and Authentication      56  

Section 2.03

  Registrar and Paying Agent      57  

Section 2.04

  Paying Agent to Hold Money in Trust      57  

Section 2.05

  Holder Lists      58  

Section 2.06

  Transfer and Exchange      58  

Section 2.07

  Replacement Notes      71  

Section 2.08

  Outstanding Notes      71  

Section 2.09

  Treasury Notes      71  

Section 2.10

  Temporary Notes      72  

Section 2.11

  Cancellation      72  

Section 2.12

  Defaulted Interest      72  

ARTICLE 3

 

REDEMPTION AND PREPAYMENT

  

Section 3.01

  Notices to Trustee      72  

Section 3.02

  Selection of Notes to Be Redeemed      73  

Section 3.03

  Notice of Redemption      73  

Section 3.04

  Effect of Notice of Redemption      75  

Section 3.05

  Deposit of Redemption Price      75  

Section 3.06

  Notes Redeemed or Purchased in Part      75  

Section 3.07

  Optional Redemption      75  

Section 3.08

  Mandatory Redemption; Purchases of Notes      77  

Section 3.09

  Offer to Purchase by Application of Excess Proceeds      77  

 

i


ARTICLE 4

 

COVENANTS

  

Section 4.01

  Payment of Notes      80  

Section 4.02

  Maintenance of Office or Agency      80  

Section 4.03

  Reports      81  

Section 4.04

  Compliance Certificate      84  

Section 4.05

  Taxes      84  

Section 4.06

  Stay, Extension and Usury Laws      84  

Section 4.07

  Limitation on Restricted Payments      84  

Section 4.08

  Limitation on Dividends and Other Payment Restrictions Affecting Restricted Subsidiaries      90  

Section 4.09

  Limitation on Indebtedness, Disqualified Stock and Preferred Equity      93  

Section 4.10

  Limitation on Sales of Assets      99  

Section 4.11

  Limitation on Transactions with Affiliates      103  

Section 4.12

  Limitation on Liens      107  

Section 4.13

  [Reserved]      107  

Section 4.14

  Corporate Existence      108  

Section 4.15

  Offer to Repurchase Upon Change of Control Triggering Event      108  

Section 4.16

  Future Guarantees      110  

Section 4.17

  Designation of Restricted and Unrestricted Subsidiaries      110  

Section 4.18

  Suspension of Certain Covenants      111  

ARTICLE 5

 

SUCCESSORS

  

Section 5.01

  Merger, Consolidation or Sale of Assets      113  

Section 5.02

  Successor Corporation Substituted      115  

ARTICLE 6

 

DEFAULTS AND REMEDIES

  

Section 6.01

  Events of Default      115  

Section 6.02

  Acceleration      117  

Section 6.03

  Other Remedies      119  

Section 6.04

  Waiver of Past Defaults      120  

Section 6.05

  Control by Majority      120  

Section 6.06

  Limitation on Suits      120  

Section 6.07

  Rights of Holders of Notes to Receive Payment      121  

Section 6.08

  Collection Suit by Trustee      121  

Section 6.09

  Trustee May File Proofs of Claim      121  

Section 6.10

  Priorities      122  

Section 6.11

  Undertaking for Costs      122  

 

ii


ARTICLE 7

 

TRUSTEE

  

Section 7.01

  Duties of Trustee      123  

Section 7.02

  Rights of Trustee      124  

Section 7.03

  Individual Rights of Trustee      126  

Section 7.04

  Trustee’s Disclaimer      126  

Section 7.05

  Notice of Defaults      126  

Section 7.06

  Compensation and Indemnity      126  

Section 7.07

  Replacement of Trustee      127  

Section 7.08

  Successor Trustee by Merger, etc.      128  

Section 7.09

  Eligibility; Disqualification      128  

Section 7.10

  Security Documents      128  
ARTICLE 8   
LEGAL DEFEASANCE AND COVENANT DEFEASANCE   

Section 8.01

  Option to Effect Legal Defeasance or Covenant Defeasance      129  

Section 8.02

  Legal Defeasance and Discharge      129  

Section 8.03

  Covenant Defeasance      130  

Section 8.04

  Conditions to Legal or Covenant Defeasance      130  

Section 8.05

  Deposited Money and Government Securities to be Held in Trust; Other Miscellaneous Provisions      131  

Section 8.06

  Repayment to Issuer      132  

Section 8.07

  Reinstatement      132  
ARTICLE 9   
AMENDMENT, SUPPLEMENT AND WAIVER   

Section 9.01

  Without Consent of Holders of Notes      133  

Section 9.02

  With Consent of Holders of Notes      134  

Section 9.03

  Revocation and Effect of Consents      136  

Section 9.04

  Notation on or Exchange of Notes      137  

Section 9.05

  Trustee to Sign Amendments, etc.      137  

ARTICLE 10

 

GUARANTEES

  

Section 10.01

  Guarantee      137  

Section 10.02

  Limitation on Guarantor Liability      138  

Section 10.03

  Execution and Delivery of Guarantee      139  

Section 10.04

  Releases      139  

 

iii


ARTICLE 11

 

SATISFACTION AND DISCHARGE

  

Section 11.01

  Satisfaction and Discharge      140  

Section 11.02

  Application of Trust Money      141  

ARTICLE 12

 

COLLATERAL AND SECURITY

  

Section 12.01

  General      142  

Section 12.02

  Security Documents      142  

Section 12.03

  Recording, Registration and Opinions; Trustee’s Disclaimer Regarding Collateral      144  

Section 12.04

  Possession, Use and Release of Collateral      145  

Section 12.05

  Suits to Protect the Collateral      146  

Section 12.06

  Authorization of Receipt of Funds by the Trustee Under the Security Documents      147  

Section 12.07

  Purchaser Protected      147  

ARTICLE 13

 

MISCELLANEOUS

  

Section 13.01

  Notices      147  

Section 13.02

  Certificate and Opinion as to Conditions Precedent      149  

Section 13.03

  Statements Required in Certificate or Opinion      149  

Section 13.04

  Rules by Trustee and Agents      149  

Section 13.05

  No Personal Liability of Directors, Managers, Officers, Members, Partners, Employees and Equityholders      149  

Section 13.06

  Governing Law; Waiver of Trial by Jury; Jurisdiction      150  

Section 13.07

  No Adverse Interpretation of Other Agreements      150  

Section 13.08

  Successors      151  

Section 13.09

  Severability      151  

Section 13.10

  Execution; Counterpart Originals      151  

Section 13.11

  Table of Contents, Headings, etc.      151  

Section 13.12

  Tax Matters      151  

 

iv


EXHIBITS

 

Exhibit A-1    FORM OF NOTE DUE 2029
Exhibit A-2    FORM OF NOTE DUE 2032
Exhibit B    FORM OF CERTIFICATE OF TRANSFER
Exhibit C    FORM OF CERTIFICATE OF EXCHANGE
Exhibit D    FORM OF CERTIFICATE FROM ACQUIRING INSTITUTIONAL ACCREDITED INVESTOR
Exhibit E    FORM OF SUPPLEMENTAL INDENTURE
Exhibit F    FORM OF JUNIOR LIEN INTERCREDITOR AGREEMENT

 

v


INDENTURE dated as of October 24, 2023 between Venture Global LNG, Inc., a Delaware corporation, and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent.

W I T N E S S E T H

WHEREAS, the Issuer has duly authorized the creation of (i) an issue of $2,500,000,000 aggregate principal amount of the Issuer’s 9.500% Senior Secured Notes due 2029 (the “Initial 2029 Notes”), and (ii) an issue of $1,500,000,000 aggregate principal amount of the Issuer’s 9.875% Senior Secured Notes due 2032 (the “Initial 2032 Notes”).

WHEREAS, the Issuer has duly authorized the execution and delivery of this Indenture (as defined herein).

NOW, THEREFORE, the Issuer, the Trustee and the Collateral Agent agree as follows for the benefit of each other and for the equal and ratable benefit of the Holders (as defined herein).

ARTICLE 1

DEFINITIONS AND INCORPORATION BY REFERENCE

Section 1.01 Definitions.

2029 Notes” means the Issuer’s 9.500% Senior Secured Notes due 2029.

2032 Notes” means the Issuer’s 9.875% Senior Secured Notes due 2032.

Acquired Debt” means Indebtedness (1) of a Person or any of its Subsidiaries existing at the time such Person becomes a Restricted Subsidiary, (2) assumed in connection with the acquisition of assets from such Person, in each case whether or not incurred by such Person in connection with or in contemplation of such Person becoming a Restricted Subsidiary of the Issuer or such acquisition, or (3) of a Person at the time such Person merges with or into or consolidates or otherwise combines with the Issuer or any Restricted Subsidiary. Acquired Debt will be deemed to have been incurred, with respect to clause (1) of the preceding sentence, on the date such Person becomes a Restricted Subsidiary, with respect to clause (2) of the preceding sentence, on the date of consummation of such acquisition of assets and, with respect to clause (3) of the preceding sentence, on the date of the relevant merger, consolidation or other combination.

Additional Notes” means additional Notes (other than the Initial Notes) issued from time to time under this Indenture in accordance with Section 2.01, Section 2.02, Section 4.09 and Section 4.12 hereof.

Additional Agent” means the administrative agent and/or trustee (as applicable) or any other similar agent, representative or Person under any First Lien Financing Document, in each case, together with its successors and permitted assigns in such capacity.

 

1


Additional First Lien Debt Facility” means one or more debt facilities, commercial paper facilities or indentures that are secured equally and ratably with the Notes by the Collateral and whose Senior Class Debt Representative has become a party to an Applicable Intercreditor Agreement in accordance therewith, in each case, as amended, amended and restated, supplemented or otherwise modified, refinanced or replaced from time to time; provided that this Indenture shall not constitute an Additional First Lien Debt Facility at any time.

Additional First Lien Documents” means, with respect to any series of Additional First Lien Obligations, the notes, credit agreements, indentures, security documents and other operative agreements evidencing or governing such Indebtedness, and each other agreement entered into for the purpose of securing any series of Additional First Lien Obligations, as the same may be amended, restated, supplemented or otherwise modified from time to time.

Additional First Lien Obligations” means, with respect to any Additional First Lien Debt Facility and including, for the avoidance of doubt, the Existing Notes Obligations, (a) all principal of and interest (including, without limitation, any interest that accrues after the commencement of any case, proceeding or other action relating to the bankruptcy, insolvency or reorganization of the Issuer or any Guarantor, whether or not allowed or allowable as a claim in any such proceeding) payable with respect to such Additional First Lien Debt Facility, (b) all other amounts payable to the related Additional First Lien Secured Parties under the related Additional First Lien Documents and (c) any renewals or extensions of the foregoing.

Additional First Lien Secured Parties” means, with respect to any series of Additional First Lien Obligations, the holders of such Additional First Lien Obligations, the Additional Agent with respect thereto, any trustee or agent or any other similar agent or Person therefor under any related Additional First Lien Documents and the beneficiaries of each indemnification obligation undertaken by the Issuer or any Guarantor under any related Additional First Lien Documents.

Affiliate” means, with respect to any specified Person, any other Person directly or indirectly controlling or controlled by or under direct or indirect common control with such specified Person.

For the purposes of this definition, “control,” when used with respect to any specified Person, means the power to direct or cause the direction of the management and policies of such Person, directly or indirectly, whether through the ownership of voting securities, by contract or otherwise; and the terms “controlling” and “controlled” have meanings correlative to the foregoing.

Agent” means the Collateral Agent, any Registrar, co-registrar, Paying Agent or additional paying agent in respect of the Notes.

Applicable Intercreditor Agreement” means, as the context may require, the First Lien Intercreditor Agreement and/or the Junior Lien Intercreditor Agreement, or any Market Intercreditor Agreement or another intercreditor agreement (which may, if applicable consist of a collateral proceeds “waterfall”).

applicable law” means, except as the context may otherwise require, all applicable laws (including common law), rules, regulations, ordinances, judgments, decrees, injunctions, writs and orders of any Governmental Authority.

 

2


Applicable Procedures” means, with respect to any transfer or exchange of or for, redemption of, or notice with respect to beneficial interests in any Global Note or the redemption or repurchase of any Global Note, the rules and procedures of DTC and/or the Depositary that apply to such transfer, exchange, redemption or repurchase.

Applicable Redemption Premium” means, with respect to any Note on any redemption date, the greater of:

(1) 1.0% of the principal amount of the Note; and

(2) the excess of:

(A) the present value at such redemption date of: (i) with respect to the 2029 Notes, (x) the redemption price of such Note at November 1, 2028 (such redemption price being set forth in Section 3.07(c)), plus (y) all required remaining scheduled interest payments due on such Note through November 1, 2028, and (ii) with respect to the 2032 Notes, (x) the redemption price of such Note at February 1, 2027 (such redemption price being set forth in the table appearing in Section 3.07(d)), plus (y) all required remaining scheduled interest payments due on such Note through February 1, 2027, in each case, excluding accrued but unpaid interest to, but excluding, the redemption date and computed using a discount rate equal to the Treasury Rate as of such redemption date plus 50 basis points; over

(B) the outstanding principal amount of the Note,

as calculated by the Issuer or an agent appointed by the Issuer. For the avoidance of doubt, calculations of the Applicable Redemption Premium shall not be a duty or obligation of the Trustee, the Collateral Agent, the Registrar or any Paying Agent or any other Agent.

Asset Sale” means:

(1) the sale, lease, transfer, conveyance or other disposition of any assets by the Issuer or any of its Restricted Subsidiaries (including by way of a Sale and Leaseback Transaction) outside of the ordinary course of business; provided, however, that the sale, lease, transfer, conveyance or other disposition of all or substantially all of the assets of the Issuer and its Restricted Subsidiaries taken as a whole will be governed by Section 4.15 and/or Section 5.01 and not by Section 4.10; and

(2) the issuance of Equity Interests by any Restricted Subsidiary or the sale by the Issuer or any of its Restricted Subsidiaries of Equity Interests in any of the Restricted Subsidiaries (in each case, other than directors’ qualifying shares).

Notwithstanding the preceding, none of the following items will be deemed to be an Asset Sale:

(1) any single transaction or series of related transactions that involves assets having a Fair Market Value of less than the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period;

 

3


(2) a transfer of assets or Equity Interests between or among the Issuer and any Restricted Subsidiary, except to the extent such assets or Equity Interests constitutes or would constitute Collateral unless such assets or Equity Interests would continue to constitute Collateral following such transfer or would constitute Excluded Capital Stock following such transfer;

(3) an issuance of Equity Interests by a Restricted Subsidiary to the Issuer or to a Restricted Subsidiary;

(4) the sale, lease or other transfer of accounts receivable, inventory or other assets in the ordinary course of business, and any sale or other disposition of damaged, worn-out, surplus or obsolete assets or assets that are no longer useful in the conduct of the business of the Issuer and its Restricted Subsidiaries or economically practicable or commercially reasonable to maintain, in each case whether now owned or hereafter acquired, in each case in in the good faith determination of the Issuer;

(5) the sale, conveyance or other disposition for value of environmental attributes or energy, fuel, water or emission credits or similar rights or contracts for any of the foregoing by the Issuer or any of its Restricted Subsidiaries;

(6) licenses and sublicenses by the Issuer or any of its Restricted Subsidiaries;

(7) any surrender or waiver of contract rights or settlement, release, recovery on or surrender of contract, tort or other claims;

(8) the granting and enforcement and exercise of a Lien not prohibited by Section 4.12, and any sale, transfer or other disposition in connection therewith or deemed reasonably necessary or desirable by the Issuer in good faith for the consummation thereof;

(9) any Restricted Payment not prohibited by Section 4.07 or the proceeds of which are substantially contemporaneously used to fund a Permitted Investment or the making of a Restricted Payment not prohibited by Section 4.07, or any Permitted Investment;

(10) the sale or other disposition of cash or Cash Equivalents;

(11) the disposition of receivables in connection with the compromise, settlement or collection thereof in bankruptcy or similar proceedings;

(12) the foreclosure, condemnation, expropriation, forced dispositions, eminent domain or any similar action with respect to any property or other assets, transfers of any property that have been subject to a casualty to the respective insurer of such property as part of an insurance settlement or upon receipt of the net proceeds of such casualty event, or a surrender or waiver of contract rights or the settlement, release or surrender of contract, tort or other claims of any kind;

 

4


(13) the disposition of assets to a person who is providing services (the provision of which has been or is to be outsourced by the Issuer or any Subsidiary to such person) related to such assets;

(14) the lease (including Sale and Leaseback Transactions and inverted lease transactions), as lessor or sublessor, or license (other than any long-term exclusive license), as licensor or sublicensor, of real or personal property or intellectual property that does not materially interfere with the business of the Issuer and its Restricted Subsidiaries, taken as a whole;

(15) Sale and Leaseback Transactions, as lessee or sublessee, and other dispositions by a Non-Recourse Subsidiary in connection with Non-Recourse Financing incurred by such Non-Recourse Subsidiary;

(16) the cancellation of intercompany Indebtedness with the Issuer or any of its Restricted Subsidiaries permitted under this Indenture;

(17) swaps of assets for other similar assets or assets whose value is reasonably equivalent or greater in terms of type, value and quality, than the assets being swapped, as determined in good faith by the Issuer;

(18) the unwinding or termination of Hedging Obligations;

(19) the issuance, sale or other disposition of Equity Interests in (i) Joint Ventures or (ii) Subsidiaries, substantially all of which Subsidiaries’ or Joint Ventures’ assets are assets that, if disposed of separately, would not constitute an Asset Sale, in a single transaction or series of related transactions;

(20) dispositions of investments in Joint Ventures to the extent required by, or made pursuant to buy/sell and/or put/call arrangements between the Joint Venture parties set forth in, Joint Venture agreements and similar binding arrangements;

(21) the issuance of Equity Interests by the Issuer or a Restricted Subsidiary to the holders of its Equity Interests in accordance with the charter, partnership agreement, limited liability company agreement or other governing documents of such Person;

(22) the issuance, sale or other disposition of Equity Interests or other assets of a Non-Recourse Subsidiary; provided that any Net Proceeds of such disposition are (A) applied to Project Costs of the Project to which such Non-Recourse Subsidiary relates or to repay a Non-Recourse Financing of such Project or (B) applied in accordance with Section 4.10(b)(1);

(23) any sale, lease, conveyance or other disposition of Equity Interests in, or Indebtedness or other securities of, an Unrestricted Subsidiary;

(24) dispositions of improvements made to leased real property to landlords pursuant to customary terms of leases entered into in the ordinary course of business;

 

5


(25) the lapse or abandonment of intellectual property rights (including any registrations or applications therefor) in the ordinary course of business or consistent with industry practice, which in the reasonable good faith determination of the Issuer, are not material to the conduct of the business of the Issuer and its Subsidiaries, taken as a whole;

(26) any sale, transfer or other disposition to effect the formation of any Subsidiary that is a Delaware Divided LLC; provided that upon formation of such Delaware Divided LLC, such Delaware Divided LLC shall be a Restricted Subsidiary;

(27) any sale, transfer or other disposition in connection with, and deemed reasonably necessary or desirable by the Issuer in good faith for the consummation of, any IPO Reorganization Transactions or any Tax Restructuring;

(28) Permitted Intercompany Activities and related transactions;

(29) any Equity Financing Transaction;

(30) ECR Transactions; and

(31) (A) dispositions or discounts without recourse of accounts receivable, notes receivable, rights to payment, other current assets or participations therein, or (B) dispositions of assets in connection with any Permitted Receivables Financing Assets pursuant to any Permitted Receivables Financing (including Equity Interests in any Subsidiary all of substantially all of the assets of which are Permitted Receivables Financing Assets).

In the event that a transaction (or a portion thereof) meets the criteria of a permitted Asset Sale and would also be a permitted Restricted Payment or Permitted Investment, the Issuer, in its sole discretion, will be entitled to divide and classify such transaction (or a portion thereof) as an Asset Sale and/or one or more of the types of permitted Restricted Payments or Permitted Investments.

Asset Sale Prepayment Percentage” means 100%; provided that if, at the time of receipt by the Issuer or the relevant Restricted Subsidiary of the Net Proceeds from any Asset Sale (or at any time during the applicable reinvestment period described herein), on a pro forma basis after giving effect to the applicable Asset Sale and the application of the Net Proceeds therefrom, (i) the Holdco Debt Ratio is less than or equal to 0.95 to 1.00 and greater than 0.70 to 1.00, such percentage shall instead be 50% or (ii) the Holdco Debt Ratio is less than or equal to 0.70 to 1.00, such percentage shall instead be 0%.

Bank Product Obligations” means all obligations and liabilities of any kind, nature or character (whether direct or indirect, absolute or contingent, liquidated or unliquidated, voluntary or involuntary, due or to become due that are in existence on the Issue Date or thereafter incurred) of the Issuer or any Restricted Subsidiary, whether on account of principal, interest, reimbursement obligations, fees, indemnities, costs, expenses or otherwise, which may arise under, out of, or in connection with any treasury, investment, depository, clearing house, wire transfer, commercial credit card, purchasing card, merchant card, cash management or automated clearing house transfers of funds services or any related services, including all renewals, extensions and modifications thereof and all costs, attorneys’ fees and expenses incurred by a holder of Bank Product Obligations in connection with the collection or enforcement thereof.

 

6


Bankruptcy Code” means Title 11 of the United States Code (11 U.S.C. § 101 et seq.), as amended.

Bankruptcy Law” means the Bankruptcy Code and any other state or federal insolvency, reorganization, moratorium or similar law for the relief of debtors.

Beneficial Owner” has the meaning assigned to such term in Rule 13d-3 and Rule 13d-5 under the Exchange Act. The terms “Beneficially Owns,” “Beneficially Owned” and “Beneficial Ownership” have a corresponding meaning.

Board of Directors” means:

(1) with respect to a corporation, the board of directors of the corporation (including any committee thereof duly authorized to act on behalf of such board);

(2) with respect to a partnership having only one general partner, the board of directors of the general partner of the partnership;

(3) with respect to a limited liability company, the managing member or members or any controlling committee of managing members or other governing body thereof; and

(4) with respect to any other Person, the board or committee of such Person serving a similar function.

Business Day” means a day other than a Saturday, Sunday or other day on which banking institutions in New York or a place of payment under this Indenture are authorized or required by law to close.

Capital Stock” means:

(1) in the case of a corporation or company, corporate stock or shares;

(2) in the case of an association or business entity, any and all shares, interests, participations, rights or other equivalents (however designated) of corporate stock;

(3) in the case of a partnership or limited liability company, partnership interests (whether general or limited) or membership interests; and

(4) any other interest or participation that confers on a Person the right to receive a share of the profits and losses of, or distributions of assets of, the issuing Person, but excluding from all of the foregoing any debt securities convertible into Capital Stock, whether or not such debt securities include any right of participation with Capital Stock.

 

7


Captive Insurance Subsidiary” means (a) any Subsidiary of the Issuer operating for the purpose of (i) insuring the businesses, operations or properties owned or operated by any Parent Entity, the Issuer or any of its Subsidiaries, including their future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members), and related benefits and/or (ii) conducting any activities or business incidental thereto (it being understood and agreed that activities which are relevant or appropriate to qualify as an insurance company for U.S. federal or state tax purposes shall be considered “activities or business incidental thereto”) or (b) any Subsidiary of any such insurance subsidiary operating for the same purpose described in clause (a) above.

Cash Equivalents” means, as at any date of determination, any of the following: (i) marketable securities (a) issued or directly and unconditionally guaranteed as to interest and principal by the United States government or (b) issued by any agency of the United States the obligations of which are backed by the full faith and credit of the United States, in each case maturing within one year after such date; (ii) marketable direct obligations issued by any state of the United States of America or any political subdivision of any such state or any public instrumentality thereof, in each case maturing within one year after such date and having, at the time of the acquisition thereof, a rating of at least A-1 from S&P or at least P-1 from Moody’s; (iii) commercial paper maturing no more than three months from the date of creation thereof and having, at the time of the acquisition thereof, a rating of at least A-1 from S&P or at least P-1 from Moody’s; (iv) certificates of deposit or bankers’ acceptances maturing within three months after such date and issued or accepted by any lender or by any commercial bank organized under the laws of the United States of America or any state thereof or the District of Columbia that (a) is at least “adequately capitalized” (as defined in the regulations of its primary Federal banking regulator) and (b) has Tier 1 capital (as defined in such regulations) of not less than $1,000,000,000; and (v) shares of any money market mutual fund that (a) has substantially all of its assets invested continuously in the types of investments referred to in clauses (i) and (ii) above, (b) has net assets of not less than $5,000,000,000, and (c) has the highest rating obtainable from either S&P or Moody’s.

Change of Control” means the occurrence of any of the following:

(1) the consummation of any transaction (including, without limitation, any merger or consolidation) the result of which is that any “person” or “group” of related persons (as such terms are used in Section 13(d)(3) of the Exchange Act) other than any of the Permitted Holders, becomes the beneficial owner (as such term is defined in Rules 13d- 3 and Rule 13d-5 under the Exchange Act), directly or indirectly, of more than 50% of the voting power of the Voting Stock of the Issuer (or its successors by merger, consolidation or purchase of all or substantially all of its assets); or

(2) the direct or indirect sale, lease, transfer, conveyance or other disposition (other than by way of merger or consolidation), in one or a series of related transactions, of all or substantially all of the properties or assets of the Issuer and its Subsidiaries taken as a whole to any “person” (as such term is used in Section 13(d)(3) of the Exchange Act) other than any of the Permitted Holders;

 

8


provided, however, that a transaction in which the Issuer becomes a Subsidiary of another Person (other than any of the Permitted Holders) shall not constitute a Change of Control if (a) the shareholders of the Issuer immediately prior to such transaction Beneficially Own, directly or indirectly through one or more intermediaries, at least a majority of the voting power of the outstanding Voting Stock of the Issuer immediately following the consummation of such transaction or (b) immediately following the consummation of such transaction, no “person” (as such term is defined above), other than such other Person (but including the holders of the Equity Interests of such other Person) and/or any of the Permitted Holders, “Beneficially Owns, directly or indirectly through one or more intermediaries, more than 50% of the voting power of the outstanding Voting Stock of the Issuer; provided further, (i) a Person or group shall not be deemed to Beneficially Own Voting Stock subject to an equity or asset purchase agreement, merger agreement, option agreement, warrant agreement or similar agreement (or voting or option or similar agreement related thereto) until the consummation of the acquisition of Voting Stock in connection with the transactions contemplated by such agreement, (ii) the phrase “person” or “group” is within the meaning of Section 13(d) or 14(d) of the Exchange Act, but excluding (A) any employee benefit plan of such Person or “group” and its subsidiaries and any Person acting in its capacity as trustee, agent or other fiduciary or administrator of any such plan and (B) any underwriter in connection with an IPO, and (iii) if any group includes one or more Permitted Holders, the issued and outstanding Voting Stock of the Issuer or the IPO Entity Beneficially Owned, directly or indirectly, by any Permitted Holders that are part of such group shall not be treated as being Beneficially Owned by such “group” or any other member of such group for purposes of determining whether a Change of Control has occurred.

Change of Control Triggering Event” means, with respect to a series of Notes, the occurrence of both a Change of Control and a Rating Decline with respect to such series of Notes.

Clearstream” means Clearstream Banking, S.A.

Code” means the United States Internal Revenue Code of 1986, as amended from time to time, and any successor statute thereto.

Collateral” means, unless released in accordance with the terms of this Indenture or the Collateral Agency Agreement and subject to the occurrence of any Reversion Date, all assets and properties subject to Liens created pursuant to the Security Documents to secure the Note Obligations and the other First Lien Obligations (other than any Excluded Asset); provided that, with respect to any cash or cash equivalents (i) collateralizing letters of credit obligations under, or (ii) deposited in a debt service reserve account relating to, in each case, one series of First Lien Obligations, such collateral shall only be for the benefit of the particular First Lien Secured Parties who issued or have participation interests in such letters of credit or such First Lien Obligations.

Collateral Agency Agreement” means the Collateral Agency Agreement dated as of May 26, 2023 among the Issuer, each other Grantor (as defined and referred to therein), the trustee for the Existing Notes, each other Senior Class Debt Representative from time to time party thereto and the Collateral Agent, as it may be amended, amended and restated, supplemented or otherwise modified from time to time.

 

9


Collateral Agent” has the meaning ascribed to such term in the Collateral Agency Agreement.

Commission” means the U.S. Securities and Exchange Commission.

continuing” means, with respect to any Default or Event of Default, that such Default or Event of Default has not been cured or waived.

Contractual Obligation” means as to any Person, any provision of any security issued by such Person or any obligation under any contract, agreement, instrument or other written undertaking to which such Person is a party or by which it or any of its property is bound.

Controlled Investment Affiliate” means, as to any Person, any other Person, which directly or indirectly is in control of, is controlled by, or is under common control with such Person and is organized by such Person (or any Person controlling such Person) primarily for making direct or indirect equity or debt investments in the Issuer and/or other companies.

Corporate Trust Office of the Trustee” means the address of the Trustee at 601 Travis Street, 16th floor, Houston, TX 77002 or such other address as to which the Trustee may give notice to the Issuer.

Credit Facilities” means one or more debt facilities, credit agreements, commercial paper facilities, note purchase agreements, indentures, or other agreements, in each case with banks, lenders, purchasers, investors, trustees, agents or other representatives of any of the foregoing, providing for revolving credit loans, term loans, receivables financing (including through the sale of receivables or interests in receivables to such lenders or other Persons or to special purpose entities formed to borrow from such lenders or other Persons against such receivables or sell such receivables or interests in receivables), or letters of credit, notes, earn-out obligations constituting Indebtedness or other borrowings or other extensions of credit, including any notes, mortgages, guarantees, collateral documents, instruments and agreements executed in connection therewith, in each case, as amended, restated, modified, renewed, refunded, restated, restructured, increased, supplemented, replaced or refinanced in whole or in part from time to time, including any replacement, refunding or refinancing facility or agreement that increases the amount permitted to be borrowed thereunder or alters the maturity thereof or adds entities as additional borrowers or guarantors thereunder and whether by the same or any other agent, lender group of lenders, counterparties or otherwise.

Cumulative Distributable Cash” means, with respect to any date of determination, the cumulative Distributable Cash for the period (taken as one accounting period) from, and including, the first day of the fiscal quarter in which the Reference Date occurs, to, and including, the end of the most recently ended fiscal quarter of the Issuer for which internal financial statements are available as of such date of determination.

Custodian” means the Trustee, as custodian with respect to the Global Notes, or any successor entity thereto.

Default” means any event that is, or with the passage of time or the giving of notice or both would be, an Event of Default.

 

10


Definitive Note” means a certificated Note registered in the name of the Holder thereof, issued in accordance with Section 2.06, substantially in the form of Exhibit A-1 and Exhibit A-2 except that such Note shall not bear the Global Note Legend and shall not have the “Schedule of Exchanges of Interests in the Global Note” attached thereto.

Delaware Divided LLC” means any Delaware LLC formed upon the consummation of a Delaware LLC Division.

Delaware LLC” means any limited liability company organized or formed under the laws of the State of Delaware.

Delaware LLC Division” means the statutory division of any Delaware LLC into two or more Delaware LLCs pursuant to Section 18-217 of the Delaware Limited Liability Company Act.

Derivative Instruments” with respect to a Person, means any contract, instrument or other right to receive payment or delivery of cash or other assets to which such Person or any Affiliate of such Person that is acting in concert with such Person in connection with such Person’s investment in the Notes (other than a Screened Affiliate) is a party (whether or not requiring further performance by such Person), the value and/or cash flows of which (or any material portion thereof) are materially affected by the value and/or performance of the Notes and/or the creditworthiness of the Issuer.

Depositary” means, with respect to the Notes issuable or issued in whole or in part in global form, any Person specified in Section 2.03 hereof as the Depositary with respect to the Notes, and any and all successors thereto appointed as Depositary hereunder and having become such pursuant to the applicable provision of this Indenture.

Designated Non-cash Consideration” means the fair market value of non-cash consideration received by the Issuer or a Restricted Subsidiary in connection with an Asset Sale that is so designated as Designated Non-cash Consideration pursuant to an Officer’s Certificate, setting forth the basis of such valuation, executed by the principal financial officer of the Issuer, less the amount of cash or Cash Equivalents received in connection with a subsequent sale of or collection on such Designated Non-cash Consideration. A particular item of Designated Non-Cash Consideration will no longer be considered to be outstanding when and to the extent it has been paid, redeemed or otherwise retired or sold or otherwise disposed of in exchange for consideration in the form of Cash Equivalents in compliance with Section 4.10.

Designated Preferred Stock” means Preferred Stock of the Issuer or any Parent Entity (in each case other than Disqualified Stock) that is issued for cash (other than to a Restricted Subsidiary or an employee stock ownership plan or trust established by the Issuer or any of its Subsidiaries) and is so designated as Designated Preferred Stock, pursuant to an Officer’s Certificate, on the issuance date thereof, the cash proceeds of which are excluded from any calculation of Incremental Funds.

Disqualified Stock” means, with respect to any Person, any Capital Stock of such Person that, by its terms (or by the terms of any security into which it is convertible or for which it is puttable or exchangeable, either mandatorily or at the option of the holder thereof), or upon the happening of any event or condition matures or is mandatorily redeemable (other than solely for

 

11


Capital Stock of such Person or any Parent Entity thereof that would not otherwise constitute Disqualified Stock, and for cash in lieu of fractional shares of Capital Stock and other than solely as a result of a change of control, asset sale, casualty, condemnation or eminent domain) pursuant to a sinking fund obligation or otherwise, or is redeemable at the option of the holder thereof (other than solely for Capital Stock of such Person or as a result of a change of control, asset sale, casualty, condemnation or eminent domain), in whole or in part, in each case prior to the date 91 days after the earlier of the maturity date of the Notes of the applicable series or the date the Notes of the applicable series are no longer outstanding; provided, however, that if such Capital Stock is issued to any future, current or former employee, director, officer, manager or consultant (or their respective Controlled Investment Affiliates or Immediate Family Members), of the Issuer, any of its Subsidiaries, any Parent Entity or any other entity in which the Issuer or a Restricted Subsidiary has an Investment and is designated in good faith as an “affiliate” by the Board of Directors of the Issuer (or the compensation committee thereof) or any other plan for the benefit of current, former or future employees (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or its Subsidiaries or by any such plan to such employees (or their respective Controlled Investment Affiliates or Immediate Family Members), such Capital Stock shall not constitute Disqualified Stock solely because it may be required to be repurchased by the Issuer or its Subsidiaries in order to satisfy applicable statutory or regulatory obligations.

Distributable Cash” means, for any period, the aggregate amount of net cash provided by (used in) operating activities of the Issuer and its Subsidiaries for such period, determined on a consolidated basis in accordance with GAAP, adjusted as follows (in each case, without duplication):

 

  (a)

decreased by the aggregate amount of net cash provided by (used in) operating activities of any Unrestricted Subsidiaries of the Issuer for such period; and

 

  (b)

increased by the sum of the following:

 

  (i)

the aggregate amount of any scheduled cash interest payments and any other debt service payments with respect to any Indebtedness of the Issuer and its Restricted Subsidiaries, solely to the extent such payments are actually made during such period using net cash provided by financing activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (ii)

the aggregate amount of any Test Revenue to the extent included in net cash provided by (used in) investing activities of the Issuer and its Restricted Subsidiaries for such period, determined on a consolidated basis in accordance with GAAP; plus

 

  (iii)

the aggregate amount of dividends, distributions or return on investment actually received by the Issuer or any of its Restricted Subsidiaries during such period in the form of cash or Cash Equivalents from any Person that is not a Restricted Subsidiary (including any Unrestricted Subsidiary, Joint Venture or investment recorded in such Person under the equity method of accounting); plus

 

12


  (iv)

solely to the extent Distributable Cash is used to determine the Fixed Charge Coverage Ratio, the aggregate amount of any operating expenses incurred by the Issuer during such period; and

 

  (c)

decreased by the sum of the following:

 

  (i)

the aggregate amount of any scheduled cash interest payments, amortization payments and any other debt service payments and repayments with respect to any Non-Recourse Financing of any Non-Recourse Subsidiary, solely to the extent such payments are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (ii)

the aggregate amount of any cash distributions or cash repurchase amounts actually paid during such period to any Person (other than the Issuer and its Restricted Subsidiaries) with respect to any Disqualified Stock or Preferred Equity issued by, or non-controlling interest in, any Non-Recourse Subsidiary, solely to the extent such distributions or repurchases are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (iii)

the aggregate amount of any mandatory payments actually made during such period with respect to any ECR Transaction, solely to the extent such payments are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (iv)

the aggregate amount of any Investments actually made by the Issuer or any of its Restricted Subsidiaries during such period in the form of cash or Cash Equivalents in any Person that is not a Restricted Subsidiary (including any Unrestricted Subsidiary, Joint Venture or Investment recorded in such Person under the equity method of accounting), solely to the extent such Investments are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; and

 

  (d)

decreased by deposits into (or increased by withdrawals from) any restricted cash accounts during such period that are required pursuant to any Non-Recourse Financing of any Non-Recourse Subsidiary (including fully funding any contingency requirements, reserving for remaining construction costs and fulfilling any debt service reserve account obligations), solely to the extent that such deposits (or withdrawals) decrease (or increase) net cash provided by (used in) operating activities of the Issuer and its Restricted Subsidiaries for such period.

Early Cargo Revenues” means, with respect to any group of Project Companies for an applicable Project, the total cash permitted to be distributed by such group of Project Companies to the Issuer prior to the applicable commercial operation date under the Non-Recourse Financing for the applicable Project.

 

13


ECR Transaction” means any transaction involving the use of Early Cargo Revenues (and no other funds of a Recourse Person) to provide credit support (contingent or otherwise), equitize or otherwise finance any Project Company in connection with a Non-Recourse Financing or Equity Financing Transaction; provided that, no Person that benefits from such ECR Transaction shall have recourse to any Recourse Person other than rights to Early Cargo Revenues actually received by any Recourse Person and (for the avoidance of doubt) shall not be entitled to any Lien on the assets of any Recourse Person.

Electronic Means” means any of the following communications methods: e-mail, facsimile transmission, secure electronic transmission containing applicable authorization codes, passwords and/or authentication keys issued by the Trustee, or another method or system specified by the Trustee as available for use in connection with its services hereunder.

Equity Financing Transaction” means any bona fide equity issuance or equity financing transaction or series of related transactions by any Non-Recourse Subsidiary (including, for the avoidance of doubt, any issuance or series of related issuances of Disqualified Stock, Preferred Equity or other Equity Interests by any Non-Recourse Subsidiary) (a) the proceeds of which are used for the financing (or refinancing) of all or any portion of any Project to which such Non- Recourse Subsidiary relates, all or any portion of any other Project Costs relating to any such Project, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith; provided that, to the extent such Disqualified Stock, Preferred Equity of other Equity Interests are issued by a Non-Recourse Subsidiary that is an obligor under any Non-Recourse Financing relating to the applicable Project, the proceeds of the issuance of such Disqualified Stock, Preferred Equity of other Equity Interests may be used for the purpose of, or in connection with, any financing (or refinancing) of all or any portion of any one or more other Projects, all or any portion of any Project Costs relating to any such one or more other Projects, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith, so long as such use of proceeds is permitted under the terms of each Non-Recourse Financing that is then outstanding to which such Non-Recourse Subsidiary is a party (and not pursuant to an amendment or waiver of any such Non-Recourse Financing in contemplation thereof); and (b) such transaction or series of related transactions does not result in such Non-Recourse Subsidiary no longer constituting a “Restricted Subsidiary” for purposes of this Indenture immediately after giving effect thereto.

Equity Interests” means Capital Stock and all warrants, options or other rights to acquire Capital Stock (but excluding any debt security that is convertible into, or exchangeable for, Capital Stock).

Equity Offerings” means any public or private sale after the Issue Date of Capital Stock of the Issuer or any Parent Entity (including an IPO), the proceeds of which have been contributed to the Issuer as common equity, other than (i) public offerings with respect to the Issuer’s common stock registered on Form S-4 or Form S-8; and (ii) issuances to the Issuer or any Subsidiary of the Issuer.

 

14


Euroclear” means Euroclear Bank, S.A./N.V.

Exchange Act” means the U.S. Securities Exchange Act of 1934, as amended, or any successor statute, and the rules and regulations promulgated by the Commission thereunder.

Excluded Assets” means (a) any asset (including any general intangibles and any contract, instrument, lease, license, permit, agreement or other document, or any property or other right subject thereto (including pursuant to a purchase money security interest, capital lease or similar arrangement or, in the case of after-acquired property, pre-existing secured Indebtedness not incurred in anticipation of the acquisition by the Issuer or any Guarantor of such property)) the grant or perfection of a security interest in which would (i) constitute a violation of a restriction in favor of a third party (other than the Issuer, any Guarantor or any Subsidiary thereof) or result in the abandonment, invalidation or unenforceability of any right or assets of the Issuer or the relevant Guarantor, as applicable, (ii) result in a breach, termination (or a right of termination) or default under any such contract, instrument, lease, license, permit, agreement or other document (including pursuant to any “change of control” or similar provision) (there being no requirement pursuant to any Note Document to obtain any consent in respect thereof from any Person that is not also the Issuer, a Guarantor or any Subsidiary thereof) or (iii) permit any Person (other than the Issuer, any Guarantor or any Subsidiary thereof) to amend any rights, benefits and/or obligations of the Issuer or the relevant Guarantor, as applicable, in respect of such relevant asset or permit such Person to require the Issuer, any Guarantor or any Subsidiary thereof to take any action materially adverse to the interests of such Subsidiary, the Issuer or Guarantor; provided, however, that any such asset will only constitute an Excluded Asset under clause (i) or clause (ii) above to the extent such violation or breach, termination (or right of termination) or default would not be rendered ineffective pursuant to Sections 9-406, 9-407, 9-408 or 9-409 of the UCC (or any successor provision or provisions) of any relevant jurisdiction or any other applicable requirement of law; provided, further, that any such asset shall cease to constitute an Excluded Asset at such time as the condition causing such violation, breach, termination (or right of termination) or default or right to amend or require other actions no longer exists and to the extent severable, the security interest granted under the applicable Security Document shall attach immediately to any portion of such general intangible or other right that does not result in any of the consequences specified in clauses (i) through (iii) above, (b) Excluded Capital Stock, (c) any intent-to-use (or similar) trademark application prior to the filing of a “Statement of Use,” “Amendment to Allege Use” or similar filing with respect thereto, only to the extent, if any, that, and solely during the period, in which, if any, the grant of a security interest therein may impair the validity or enforceability, or result in the voiding of, such intent-to-use trademark application or any registration issuing therefrom under applicable law, (d) any asset or property (including Capital Stock), the grant or perfection of a security interest in which would (A) require any governmental or regulatory consent, approval, license or authorization (there being no requirement under any Note Document to obtain the consent of any Governmental Authority or other Person (other than the Issuer, any Guarantor or any Subsidiary thereof), including, without limitation, no requirement to comply with the Federal Assignment of Claims Act or any similar statute), unless such consent, approval, license or authorization has been obtained, (B) be prohibited or restricted by applicable requirements of law (including enforceable anti-assignment provisions of applicable requirements of law), except, in the case of the foregoing clause (A) and this clause (B), to the extent such prohibition would be rendered ineffective under applicable anti-assignment provisions of the UCC of any relevant jurisdiction notwithstanding such prohibition, (C) trigger termination of any contract pursuant to

 

15


a “change of control” or similar provision and is binding on such asset on the Issue Date or at the time of its acquisition and not incurred in contemplation thereof; it being understood that “Excluded Assets” shall not include proceeds or receivables arising out of any contract described in this clause (d) to the extent that the assignment of such proceeds or receivables is expressly deemed to be effective under the UCC or any other applicable law notwithstanding the relevant provision or (D) result in material adverse tax consequences to the Issuer, any Guarantor or any Subsidiary thereof, as determined by the Issuer in good faith, (e) (i) except to the extent a security interest therein can be perfected by the filing of a UCC financing statement, any leasehold interest and (ii) any real property or real property interest, (f) any margin stock, (g) any governmental or regulatory license or state or local franchise, charter, consent, permit or authorization to the extent the granting of a security interest therein is prohibited or restricted thereby or by applicable requirements of law, other than the proceeds thereof, the assignment of which is expressly deemed effective under the UCC notwithstanding such prohibition; provided, however, that any such asset will only constitute an Excluded Asset under this clause (g) to the extent such prohibition or restriction would not be rendered ineffective pursuant to applicable anti-assignment provisions of the UCC of any relevant jurisdiction, (h) any letter of credit right (other than to the extent a security interest in such letter of credit right can be perfected by filing an “all-assets” UCC financing statement) and all commercial tort claims, (i) any cash or Cash Equivalents (other than cash and Cash Equivalent representing identifiable proceeds of other Collateral, a security interest in which can be perfected through the filing of an “all-assets” UCC financing statement), (j) any deposit account or commodity or securities account (excluding any securities entitlements and any related assets to the extent a security interest therein can be perfected through the filing of an “all assets” UCC financing statement; it being understood that this exception does not apply to cash or Cash Equivalents other than cash and Cash Equivalents representing identifiable proceeds of other Collateral), (k) any motor vehicle, airplane or other asset subject to a certificate of title (other than to the extent a security interest therein can be perfected by filing an “all assets” UCC financing statement and without the requirement to list any VIN, serial or similar number), (l) any asset with respect to which the Collateral Agent and the Issuer or the relevant Guarantor, as applicable, have reasonably determined that the cost, burden, difficulty or consequence (including any effect on the ability of the Issuer or the relevant Guarantor, as applicable, to conduct its operations and business in the ordinary course of business) of obtaining or perfecting a security interest therein outweighs the benefit of a security interest to the relevant Notes Parties afforded thereby and (m) except for the Issuer, all assets and property of any other Person other than Pledged Equity and the proceeds thereof.

Excluded Capital Stock” means the Capital Stock of any Subsidiary of the Issuer that is (i) not a Wholly-Owned Subsidiary directly owned by the Issuer or any Guarantor, (ii) an Immaterial Subsidiary or (iii) an Unrestricted Subsidiary.

Existing 2028 Notes” means the aggregate principal amount of the Issuer’s 8.125% Senior Secured Notes due 2028 outstanding on the Issue Date.

Existing 2031 Notes” means the aggregate principal amount of the Issuer’s 8.375% Senior Secured Notes due 2031 outstanding on the Issue Date.

Existing Indebtedness” means any Indebtedness, Disqualified Stock and Preferred Stock of the Issuer and its Restricted Subsidiaries (other than the Notes, the Guarantees and Indebtedness that constitutes Non-Recourse Financing that is incurred by a Non-Recourse Subsidiary) outstanding on the Issue Date.

 

16


Existing Indenture” means the indenture, dated as of May 26, 2023, between the Issuer and The Bank of New York Mellon Trust Company, N.A., as trustee and collateral agent, and the guarantors from time to time party thereto, governing the Existing Notes, as amended, supplemented or modified from time to time.

Existing Notes” means the Existing 2028 Notes and the Existing 2031 Notes.

Existing Notes Documents” means the Existing Indenture (including any guarantees), the Existing Notes and the Security Documents.

Existing Notes Obligations” means all obligations of the Issuer and the guarantors under the Existing Indenture (including any guarantees), the Existing Notes and the Security Documents.

Existing Notes Parties” means, collectively, the trustee for the holders of the Existing Notes, the collateral agent, each other agent, and the holders of the Existing Notes, in each case, under the Existing Indenture.

Fair Market Value” means the value that would be paid by a willing buyer to an unaffiliated willing seller in a transaction not involving distress of either party, as determined by the Issuer in good faith.

Finance Lease Obligations” means an obligation that is required to be classified and accounted for as a finance lease for financial reporting purposes on the basis of GAAP. The amount of such obligation will be the capitalized amount of such obligation at the time any determination thereof is to be made as determined on the basis of GAAP.

First Lien Financing Document” means (i) the Notes Documents, (ii) the Existing Notes Documents and (iii) each Additional First Lien Document.

First Lien Intercreditor Agreement” means the first lien intercreditor agreement, dated as of September 28, 2023, among the trustee for the holders of the Existing Notes, the Collateral Agent and the senior class debt representatives from time to time party thereto, and acknowledged by the Company and the other grantors from time to time party thereto, as amended, supplemented or modified from time to time.

First Lien Obligations” means (i) the Note Obligations, (ii) the Existing Notes Obligations and (iii) any Additional First Lien Obligations.

First Lien Secured Parties” means (i) the Collateral Agent, (ii) the Notes Parties, (iii) the Existing Notes Parties and (iv) the Additional First Lien Secured Parties with respect to each series of Additional First Lien Obligations.

 

17


Fixed Charge Coverage Ratio” means as of any date of determination, the ratio of: (x) the aggregate amount of Distributable Cash for the applicable Test Period plus the aggregate amount of Fixed Charges for the applicable Test Period to (y) the aggregate amount of the Fixed Charges for the applicable Test Period. In the event that the Issuer or any Restricted Subsidiary (other than any Non-Recourse Subsidiary) incurs, assumes, guarantees, redeems, repays, retires or extinguishes any Indebtedness (other than Indebtedness incurred or repaid under any revolving credit facility unless such Indebtedness has been permanently repaid and has not been replaced) or issues or redeems Disqualified Stock or Preferred Equity subsequent to the commencement of the period for which the Fixed Charge Coverage Ratio is being calculated but prior to or simultaneously with the event for which the calculation of the Fixed Charge Coverage Ratio is made (the “Calculation Date”), then the Fixed Charge Coverage Ratio shall be calculated giving pro forma effect to such incurrence, assumption, guarantee, redemption, repayment, defeasance, discharge, retirement or extinguishment of Indebtedness, or such issuance or redemption of Disqualified Stock or Preferred Equity, as if the same had occurred at the beginning of the applicable four-quarter period.

In addition, for purposes of making the computation referred to above,

(1) Investments, acquisitions, dispositions, mergers, amalgamations, consolidations and discontinued operations (as determined in accordance with GAAP) that have been made by the Issuer or any of its Subsidiaries during the Test Period or subsequent to such Test Period and on or prior to or simultaneously with the Calculation Date shall be calculated on a pro forma basis assuming that all such Investments, acquisitions, dispositions, mergers, amalgamations, consolidations and discontinued operations (and the change in any associated fixed charge obligations and the change in Distributable Cash resulting therefrom) had occurred on the first day of the Test Period;

(2) if since the beginning of the Test Period, any Person that subsequently became a Subsidiary or was merged with or into the Issuer or any of its Subsidiaries since the beginning of such period shall have made any Investment, acquisition, disposition, merger, amalgamation, consolidation or discontinued operation that would have required adjustment pursuant to this definition, then the Fixed Charge Coverage Ratio shall be calculated giving pro forma effect thereto for such period as if such Investment, acquisition, disposition, merger, amalgamation, consolidation or discontinued operation had occurred at the beginning of the applicable Test Period;

(3) any Person that is a Restricted Subsidiary or a Subsidiary on the Calculation Date will be deemed to have been a Restricted Subsidiary or a Subsidiary, as applicable, at all times during the applicable Test Period, and any Person that is not a Restricted Subsidiary or a Subsidiary on the Calculation Date will be deemed not to have been a Restricted Subsidiary or a Subsidiary, as applicable, at any time during the Test Period;

(4) if any Indebtedness bears a floating rate of interest, the interest expense on such Indebtedness will be calculated as if the rate in effect on the Calculation Date had been the applicable rate for the entire period (taking into account any Hedging Obligation applicable to such Indebtedness);

(5) interest on a Finance Lease Obligation shall be deemed to accrue at an interest rate reasonably determined by a responsible financial or accounting officer of the Issuer to be the rate of interest implicit in such Finance Lease Obligation in accordance with GAAP; and

 

18


(6) interest on Indebtedness that may optionally be determined at an interest rate based upon a factor of a prime or similar rate, a eurocurrency interbank offered rate, or other rate, shall be deemed to have been based upon the rate actually chosen, or, if none, then based upon such optional rate chosen as the Issuer may designate.

For purposes of this definition, whenever pro forma effect is to be given to an acquisition or disposition of assets, the amount of income or earnings relating thereto and the amount of Fixed Charges associated with any Indebtedness incurred in connection therewith, the pro forma calculations shall be determined in good faith by the Issuer (and may include, for the avoidance of doubt, cost savings, operating expense reductions and synergies resulting from such Investment, acquisition, disposition, merger, amalgamation, consolidation, discontinued operation, operational change, business expansion or other transaction which is being given pro forma effect).

Fixed Charges” means, for any period, without duplication, the sum of:

(1) consolidated interest expense of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) for such period including, with respect to the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) (a) amortization of original issue discount resulting from the issuance of Indebtedness at less than par, (b) all commissions, discounts and other fees and charges owed with respect to letters of credit, bank guarantees or bankers acceptances, (c) the interest component of Finance Lease Obligations, and (d) net payments, if any made (less net payments, if any, received), pursuant to interest rate Hedging Obligations with respect to Indebtedness, but excluding (i) annual agency fees paid to the administrative agents and collateral agents under any credit facilities, (ii) costs associated with obtaining Hedging Obligations and breakage costs in respect of Hedging Obligations related to interest rates, (iii) penalties and interest relating to taxes, (iv) amortization or expensing of deferred financing fees, amendment and consent fees, debt issuance costs, commissions, fees and expenses and discounted liabilities, (v) any expensing of bridge, commitment and other financing fees and any other fees related to any acquisitions, (vi) commissions, discounts, yield and other fees and charges (including any interest expense) related to any Permitted Receivables Financing, (vii) any accretion of accrued interest on discounted liabilities and any prepayment premium or penalty, (viii) any interest expense attributable to obligations of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) that are classified as “capital lease obligations” under GAAP due to the consolidation of variable interest entities and (ix) any “additional interest” or “liquidated damages” with respect to other securities for failure to timely comply with registration rights obligations ; plus

(2) cash dividends on any Disqualified Stock or Preferred Equity of the Issuer or any Restricted Subsidiary (other than Non-Recourse Subsidiaries), provided that any Disqualified Stock of the Issuer or any Restricted Subsidiary (other than Non-Recourse Subsidiaries) and any Preferred Equity of any Restricted Subsidiary (other than Non- Recourse Subsidiaries) is incurred in accordance with Section 4.09, plus

 

19


(3) consolidated capitalized interest of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) for such period, whether paid or accrued.

For purposes of this definition, interest on a Finance Lease Obligation shall be deemed to accrue at an interest rate reasonably determined by such Person to be the rate of interest implicit in such Finance Lease Obligation in accordance with GAAP.

GAAP” means generally accepted accounting principles in the United States of America as in effect from time to time; provided, that if any such accounting principle changes after the Issue Date, the Issuer may, at its option, elect to employ such accounting principle or (2) if elected by the Issuer by written notice to the Trustee in any accounting principles that are recognized as being generally accepted as set forth above which are in effect from time to time, in each case as in effect on the first date of the period for which the Issuer makes such an election and thereafter as in effect from time to time; provided that in each case any such election, once made, shall be irrevocable. Notwithstanding any other provision contained in this Indenture, the amount of any Indebtedness under GAAP with respect to Finance Lease Obligations shall be determined in accordance with the definition of “Finance Lease Obligations.”

Global Note Legend” means the legend set forth in Section 2.06(g)(2), which is required to be placed on all Global Notes issued under this Indenture.

Global Notes” means, individually and collectively, each of the Restricted Global Notes, the Unrestricted Global Notes and any Additional Notes issued as a Global Note, substantially in the form attached as Exhibit A-1 or Exhibit A-2, deposited with or on behalf of and registered in the name of the Depositary or its nominee, issued in accordance with Section 2.01 and Section 2.06.

Government Securities” means direct obligations of, or obligations guaranteed by, the United States of America (including any agency or instrumentality thereof) for the payment of which obligations or guarantees the full faith and credit of the United States of America is pledged and which are not callable or redeemable at the issuer’s option.

Governmental Authority” means the government of the United States or any other nation, or of any political subdivision thereof, whether state or local, and any agency, authority, instrumentality, regulatory body, court, central bank or other entity exercising executive, legislative, judicial, taxing, regulatory or administrative powers or functions of or pertaining to government.

guarantee” means a guarantee other than by endorsement of negotiable instruments for collection or deposit in the ordinary course of business, of all or any part of any Indebtedness (whether arising by agreements to keep-well, to take or pay or to maintain financial statement conditions, pledges of assets or otherwise).

Guarantee” means any guarantee of the Issuer’s obligations under this Indenture and the Notes by any Restricted Subsidiary in accordance with the provisions of this Indenture. When used as a verb, “Guarantee” shall have a corresponding meaning.

Guarantors” means any Restricted Subsidiary that executes a Guarantee in accordance with the provisions of this Indenture, and their respective successors and assigns.

 

20


Hedging Obligations” means, with respect to any specified Person, the obligations of such Person under:

(1) currency exchange, interest rate or commodity swap agreements, currency exchange, interest rate or commodity cap agreements and currency exchange, interest rate or commodity collar agreements; and

(2) (i) agreements or arrangements designed to protect such Person against fluctuations in currency exchange, interest rates, commodity prices or commodity transportation or transmission pricing or availability; (ii) any netting arrangements, purchase and sale agreements for renewable energy credits, fuel purchase and sale agreements, swaps, options and other agreements entered into for hedging purposes, in each case, that fluctuate in value with fluctuations in energy, power or gas prices; and (iii) agreements or arrangements for commercial or trading activities with respect to the purchase, transmission, distribution, sale, lease or hedge of any energy related commodity or service.

Holdco Total Debt” means, as of any date, the sum of (1) the aggregate amount of all outstanding Indebtedness of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) on a consolidated basis consisting of Indebtedness for borrowed money, Finance Lease Obligations, purchase money obligations and debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit (but excluding any Non-Recourse Financing and Permitted Receivables Financings), plus (2) the aggregate amount of all outstanding Disqualified Stock of the Issuer and Disqualified Stock and Preferred Stock of its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) on a consolidated basis, with the amount of such Disqualified Stock or Preferred Stock, as applicable, equal to the greater of its voluntary or involuntary liquidation preference and its Maximum Fixed Repurchase Prices, determined on a consolidated basis in accordance with GAAP, as calculated with such pro forma adjustments as are appropriate and consistent with the pro forma adjustment provisions set forth in the definition of “Fixed Charge Coverage Ratio.” For purposes hereof, the “Maximum Fixed Repurchase Price” of any Disqualified Stock or Preferred Stock means the price at which such Disqualified Stock or Preferred Stock could be redeemed or repurchased by the issuer thereof in accordance with its terms or, if such Disqualified Stock or Preferred Stock cannot be so redeemed or repurchased, the fair market value of such Disqualified Stock or Preferred Stock (as determined in good faith by the Issuer), determined on any date on which Holdco Total Debt shall be required to be determined.

Holdco Debt Ratio” means, for any Test Period, the ratio of (1) Holdco Total Debt as of the end of such Test Period to (2) Distributable Cash for such Test Period, in each case with such pro forma adjustments to Holdco Total Debt and Distributable Cash as are appropriate, in each case as calculated with such pro forma adjustments as are appropriate and consistent with the pro forma adjustment provisions set forth in the definition of “Fixed Charge Coverage Ratio,” as determined in good faith by the Issuer.

Holder” means a Person in whose name a Note is registered.

IAI Global Note” means a Global Note other than a Regulation S Global Note or a Rule 144A Global Note, issued in connection with a transfer of a Note or an interest therein to an Institutional Accredited Investor in reliance on an exemption from the registration requirements of the Securities Act.

 

21


Immaterial Subsidiary” means, as of any date, any Restricted Subsidiary that does not have consolidated assets in excess of 5.0% of consolidated total assets of the Issuer and its Restricted Subsidiaries as of the last day of the applicable Test Period; provided that, the consolidated total assets (as so determined) of all Immaterial Subsidiaries shall not exceed 10.0% of consolidated total assets of the Issuer and its Restricted Subsidiaries as of the last day of the applicable Test Period; provided, further, that, any direct Wholly-Owned Subsidiary of the Issuer that owns, directly or indirectly, all or a portion of the Calcasieu Pass Project, the TransCameron pipeline, the Plaquemines Project, the Gator Express pipeline, the CP2 Project, the CP2 Express pipeline, the Delta Project and/or the Delta Express pipeline shall not, in any event, be an Immaterial Subsidiary.

Immediate Family Members” means, with respect to any individual, such individual’s child, stepchild, grandchild or more remote descendant, parent, stepparent, grandparent, spouse, former spouse, qualified domestic partner, sibling, mother-in-law, father-in-law, son-in-law and daughter-in-law (including adoptive relationships, the estate of such individual and such other individuals above) and any trust, partnership or other bona fide estate-planning vehicle the only beneficiaries of which are any of the foregoing individuals or any private foundation or fund that is controlled by any of the foregoing individuals or any donor-advised fund of which any such individual is the donor.

Indebtedness” means, with respect to any specified Person, any indebtedness of such Person (excluding accrued expenses and trade payables, except as provided in clause (5) below), whether or not contingent:

(1) in respect of borrowed money;

(2) evidenced by bonds, notes, debentures or similar instruments or letters of credit (or reimbursement agreements in respect thereof);

(3) in respect of banker’s acceptances;

(4) representing Finance Lease Obligations in respect of sale and leaseback transactions;

(5) obligations representing the balance of deferred and unpaid purchase price of any property or services with a scheduled due date more than six months after such property is acquired or such services are completed; or

(6) representing the net amount owing under any Hedging Obligations,

if and to the extent any of the preceding items (other than letters of credit and Hedging Obligations) would appear as a liability upon a balance sheet of the specified Person prepared in accordance with GAAP.

 

22


In addition, the term “Indebtedness” includes all Indebtedness of others secured by a Lien on any asset of the specified Person (whether or not such Indebtedness is assumed by the specified Person) and, to the extent not otherwise included, the guarantee by the specified Person of any Indebtedness of any other Person; provided that the amount of such Indebtedness shall be deemed not to exceed the lesser of the amount secured by such Lien and the value of the Person’s property securing such Lien.

For the avoidance of doubt and notwithstanding the foregoing, the term “Indebtedness” will not include: (i) non-interest bearing installment obligations, contingent obligations and accrued liabilities, in each case that are incurred in the ordinary course of business and are not more than 90 days past due; (ii) obligations (a) in respect of any acquisition or contribution agreement with respect to any Permitted Investment (other than obligations constituting Indebtedness pursuant to clause (5) of this definition), or (b) existing by virtue of rights of a Non- Recourse Subsidiary under a Project Obligation collaterally assigned to a creditor, which rights may be exercised pursuant to such Project Obligation against the Issuer or any Restricted Subsidiary that is party to such Project Obligation, (iii) any prepayments or deposits received from customers or obligations in respect of funds held on behalf of customers (including, without limitation, in relation to periodic purchase volume or sales incentive rebates), in each case, in the ordinary course of business, (iv) any obligations under any license, permit or approval or guarantees thereof incurred prior to the Issue Date in the ordinary course of business, (v) in connection with the purchase by the Issuer or any Restricted Subsidiary of any business or project, any post-closing payment adjustments to which the seller may become entitled to the extent such payment is determined by a final closing balance sheet or such payment depends on the performance of such business after the closing (other than obligations constituting Indebtedness pursuant to clause (5) of this definition); provided, however, that, at the time of closing, the amount of any such payment is not determinable and, to the extent such payment thereafter becomes fixed and determined, the amount is paid in a timely manner; and (vi) any Capital Stock.

Indenture” means this indenture, as amended, supplemented or otherwise modified from time to time.

Indirect Participant” means a Person who holds a beneficial interest in a Global Note through a Participant.

Initial Notes” means the Initial 2029 Notes and the Initial 2032 Notes.

Initial 2029 Notes” has the meaning assigned to it in the recitals to this Indenture. “Initial 2032 Notes” has the meaning assigned to it in the recitals to this Indenture. “Initial Purchasers” means J.P. Morgan Securities LLC, BofA Securities, Inc., Goldman Sachs & Co. LLC, Mizuho Securities USA LLC, BBVA Securities Inc., Deutsche Bank Securities Inc., ICBC Standard Bank Plc, ING Financial Markets LLC, MUFG Securities Americas Inc., Natixis Securities Americas LLC, RBC Capital Markets, LLC, Santander US Capital Markets LLC, Scotia Capital (USA) Inc., SMBC Nikko Securities America, Inc., Wells Fargo Securities, LLC, DZ Financial Markets LLC, Loop Capital Markets LLC, National Bank of Canada Financial Inc., Raymond James & Associates, Inc., R. Seelaus & Co., LLC. and Regions Securities LLC.

 

23


Institutional Accredited Investor” means an institution that is an “accredited investor” as defined in Rule 501(a)(1), (2), (3) or (7) under the Securities Act, who are not also QIBs.

Interest Payment Date” means February 1 and August 1 of each year, beginning on August 1, 2024.

Investment” means, with respect to any Person, all direct or indirect investments by such Person in other Persons in the forms of loans (including guarantees or other obligations), advances or capital contributions, purchases or other acquisitions for consideration of Indebtedness, Equity Interests or other securities.

For purposes of Section 4.07, “Investment” will include the portion (proportionate to the Issuer’s equity interest in a Restricted Subsidiary to be designated as an Unrestricted Subsidiary) of the Fair Market Value of the net assets of such Restricted Subsidiary of the Issuer at the time that such Restricted Subsidiary is designated an Unrestricted Subsidiary; provided, however, that upon a redesignation of such Subsidiary as a Restricted Subsidiary, the Issuer will be deemed to continue to have a permanent “Investment” in an Unrestricted Subsidiary in an amount (if positive) equal to (a) the Issuer’s “Investment” in such Subsidiary at the time of such redesignation less (b) the portion (proportionate to the Issuer’s equity interest in such Subsidiary) of the Fair Market Value of the net assets of such Subsidiary at the time that such Subsidiary is so re-designated a Restricted Subsidiary.

Investment Grade Rating” means: (a) with respect to S&P, any of the categories from and including AAA to and including BBB- (or equivalent successor categories); (b) with respect to Moody’s, any of the categories from and including Aaa to and including Baa3 (or equivalent successor categories); and (c) with respect to Fitch, any of the categories from and including AAA to and including BBB- (or equivalent successor categories).

Investors” means (a) the VGP Investor, (b) the Management Investors and (c) other holders of Equity Interests in the Issuer or VG Holdings on the Issue Date.

Issue Date” means October 24, 2023.

Issuer” means Venture Global LNG, Inc., and any and all successors thereto.

IPO” means (a) the issuance by the Issuer or any Parent Entity of common Equity Interests in an underwritten public offering (other than a public offering pursuant to a registration statement on Form S-8 or comparable filing in any other applicable jurisdiction) pursuant to an effective registration statement filed with the Commission or any other comparable Governmental Authority in any other applicable jurisdiction or pursuant to Rule 144A (whether as a primary offering, a secondary public offering or a combination thereof) and (b) any other transaction or series of related transactions (including any acquisition by, or combination or other similar transaction with, a special purpose acquisition company that (i) is an entity organized or existing under the laws of the U.S., any state thereof or the District of Columbia, (ii) prior to the IPO engaged in no material business or activity other than those related to becoming and acting as a special purpose acquisition company and consummating the IPO and (iii) immediately prior to the IPO had no material assets other than cash and Cash Equivalents) that results in any of the common Equity Interests of the Issuer or any Parent Entity being publicly traded on any U.S. national securities exchange or over-the-counter market or any analogous exchange or market.

 

24


IPO Reorganization Transactions” means, collectively, the transactions effected in connection with and reasonably related to consummating an IPO.

Joint Venture” means any Person that is not a direct or indirect Subsidiary of the Issuer in which the Issuer or any of its Restricted Subsidiaries makes any Investment.

Junior Lien Obligations” means the obligations with respect to Indebtedness permitted to be incurred under this Indenture, which is by its terms intended to be secured by a Lien on the Collateral that is junior to the Lien on the Collateral that secures the Notes and the Guarantees; provided such Lien is not prohibited by the terms of this Indenture; provided, further, that (i) the holders of such Indebtedness, or the representative of such holders, shall become party to an Applicable Intercreditor Agreement and any other applicable intercreditor agreements, in each case, agreeing to be bound thereby and (ii) the Issuer has designated such Indebtedness as “Junior Lien Obligations” under such Applicable Intercreditor Agreement.

Junior Lien Representative” means in the case of any Junior Lien Obligations incurred after the Issue Date, the trustee, administrative agent, collateral agent, security agent or similar agent under the credit agreement, indenture or other operative documents governing such Junior Lien Obligations that is named as the representative in respect of such Junior Lien Obligations in the Junior Lien Intercreditor Agreement or joinder thereto.

Junior Lien Secured Parties” means with respect to any Junior Lien Obligation, all lenders, holders, trustees or agents to which such Junior Lien Obligations are owing.

Lien” means, with respect to any asset:

(1) any mortgage, deed of trust, deed to secure debt, lien (statutory or otherwise), pledge, hypothecation, encumbrance, restriction, collateral assignment, charge or security interest in, on or of such asset;

(2) the interest of a vendor or a lessor under any conditional sale agreement, capital lease or title retention agreement (or any financing lease having substantially the same economic effect as any of the foregoing) relating to such asset; and

(3) in the case of Equity Interests or debt securities, any purchase option, call or similar right of a third party with respect to such Equity Interests or debt securities.

“Limited Condition Transaction” means the entering into or consummation of any transaction (including any Restricted Payment, Change of Control, acquisition (whether by merger, consolidation or other business combination or the acquisition of capital stock, Indebtedness or otherwise) or other Investment by the Issuer or one or more of its Restricted Subsidiaries).

 

25


Long Derivative Instruments” means, as to any person, a Derivative Instrument (i) the value of which to such person generally increases, and/or the payment or delivery obligations of such person under which generally decrease, with positive changes in the financial performance and/or position of the Issuer and/or (ii) the value of which to such person generally decreases, and/or the payment or delivery obligations of such person under which generally increase, with negative changes in the financial performance and/or position of the Issuer.

Management Advances” means loans or advances made to, or guarantees with respect to loans or advances made to, directors, officers, employees or consultants (or their respective Controlled Investment Affiliates or Immediate Family Members) of any Parent Entity, the Issuer or any Restricted Subsidiary:

(1) (a) in respect of travel, entertainment, relocation or moving related expenses, payroll advances, deferred compensation and other analogous or similar expenses or payroll expenses, in each case incurred in the ordinary course of business or consistent with past practice or industry norms, or in connection with any Investment or acquisition (by meter, consolidation, amalgamation or otherwise) that is not prohibited by this Indenture, or (b) for purposes of funding any such Person’s purchase or redemption of Capital Stock (or similar obligations) of the Issuer, its Subsidiaries or any Parent Entity that is not prohibited by Section 4.07;

(2) in respect of relocation or moving related expenses, payroll advances and other analogous or similar expenses or payroll expenses, in each case incurred in connection with any closing or consolidation of any facility or office; or

(3) not exceeding $10 million in the aggregate outstanding at the time of incurrence.

Management Investors” means any individual who is a future, current or former officer, director, manager, member, member of management, employee, consultant or independent contractor of the Issuer, any Subsidiary or any Parent Entity who are (directly or indirectly through one or more investment vehicles) holders of Equity Interests in the Issuer and/or any Parent Entity and their Permitted Transferees.

Market Capitalization” means an amount equal to (i) the total number of issued and outstanding shares of common Capital Stock of the Issuer or any Parent Entity on the date of the declaration of a Restricted Payment permitted pursuant to Section 4.07(b)(20) multiplied by (ii) the arithmetic mean of the closing prices per share of such common Capital Stock on the principal securities exchange on which such common Capital Stock is traded for the 30 consecutive trading days immediately preceding the date of declaration of such Restricted Payment.

Market Intercreditor Agreement” means an intercreditor or subordination agreement or arrangement (which may take the form of a “waterfall” or similar provision) the terms of which are (a) consistent with market terms governing intercreditor arrangements for the sharing or subordination of Liens or arrangements relating to the distribution of payments in respect of Collateral, as applicable, at the time the applicable agreement or arrangement is proposed to be established in light of the type of Indebtedness subject thereto or (b) in the event an Intercreditor Agreement has been entered into after the Issue Date, the terms of which are, taken as a whole, not materially less favorable to the holders of the Notes than the terms of such Intercreditor Agreement to the extent such agreement governs similar priorities, in each case of clauses (a) and (b) as determined by the Issuer in good faith.

 

26


Net Proceeds” means the aggregate cash proceeds received by the Issuer or any of its Restricted Subsidiaries in respect of any Asset Sale (including, without limitation, any cash received upon the sale or other disposition of any non-cash consideration or Cash Equivalents substantially concurrently received in any Asset Sale), net of (i) the direct costs relating to such Asset Sale, including, without limitation, legal, accounting and investment banking fees, and sales commissions, and any relocation expenses incurred as a result of the Asset Sale, (ii) all Taxes paid or reasonably estimated to be payable as a result of the Asset Sale, (iii) all distributions and other payments required to be made to minority interest holders (other than the Issuer or any Subsidiary) in Subsidiaries or Joint Ventures as a result of such Asset Sale, (iv) all payments made on any Indebtedness which is secured by any assets subject to such Asset Sale, in accordance with the terms of any Lien upon such assets, provided that if such Indebtedness is revolving Indebtedness the related commitments are terminated, or which by applicable law are required to be repaid out of the proceeds from such Asset Sale, (v) any funded escrow established pursuant to the documents evidencing such sale or disposition to secure and indemnification obligation on adjustments to the purchase price associated with any such Asset Sale, and (vi) any reserve against liabilities associated with such Asset Sale, including pension and other post-employment benefit liabilities, liabilities related to environmental matters and indemnification obligations associated with such Asset Sale, with any subsequent reduction of the reserve other than by payments made and charged against the reserved amount to be deemed a receipt of cash.

Net Short” means, with respect to a holder or beneficial owner, as of a date of determination, either (i) the value of its Short Derivative Instruments exceeds the sum of (x) the value of its Notes plus (y) the value of its Long Derivative Instruments as of such date of determination or (ii) it is reasonably expected that such would have been the case were a Failure to Pay or Bankruptcy Credit Event (each as defined in the 2014 ISDA Credit Derivatives Definitions) to have occurred with respect to the Issuer immediately prior to such date of determination.

Non-Recourse Financing” means any Indebtedness (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness):

(1) as to which no Recourse Person provides any guarantee or other credit support (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness) or is directly or indirectly liable (as a guaranteeing person or otherwise) or has granted a Lien on any of its assets as security (or has any obligation, contingent or otherwise, to do so), other than, in each case, (i) customary carve-out matters for which a Recourse Person acts as a guarantor in connection with such Indebtedness, such as, without limitation, fraud, misappropriation, breach of representation and warranty and misapplication, (ii) any guarantees or other credit support of such Indebtedness by a Recourse Person made pursuant to Section 4.09(a) or that would otherwise constitute Permitted Debt, in each case, so long as such Recourse Person becomes a Guarantor to the extent required under Section 4.16, (iii) any Permitted Project Undertakings, (iv) any guarantees or other credit support in connection with any ECR Transaction, (v) any Standard Securitization Undertakings, and (vi) any Permitted Intercompany Activities; and

 

27


(2) which is incurred by one or more Non-Recourse Subsidiaries (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness) for the purpose of, or in connection with, any financing (or refinancing) of all or any portion of any Project to which such Non-Recourse Subsidiaries relate, all or any portion of any Project Costs relating to any such Project, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith; provided that, to the extent such Non-Recourse Financing is incurred by a Non-Recourse Subsidiary that is an obligor under any Non-Recourse Financing relating to the applicable Project that is not structurally or otherwise subordinated or junior to any other Non-Recourse Financing for such Project, the proceeds of such Non-Recourse Financing being incurred may be used for the purpose of, or in connection with, any financing (or refinancing) of all or any portion of any one or more other Projects, all or any portion of any Project Costs relating to any such one or more other Projects, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith, so long as such use of proceeds is permitted under the terms of each Non-Recourse Financing that is then outstanding in respect of the Project to which such Non-Recourse Subsidiary is a party (and not pursuant to an amendment or waiver of any such Non-Recourse Financing in contemplation thereof).

Non-Recourse Subsidiary” means each of the following, as determined at any time and from time to time by the Issuer in good faith:

(1) any Restricted Subsidiary of the Issuer that (i) is a Project Company, (ii) has no Subsidiaries and owns no material businesses or assets other than those Subsidiaries, businesses and assets reasonably necessary, appropriate or desirable for, or reasonably related or ancillary to, no more than one individual Project or other activities reasonably related or ancillary thereto, or necessary, appropriate or desirable in connection therewith, and (iii) has no Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit then outstanding other than any Non-Recourse Financing, Indebtedness arising from Permitted Intercompany Activities or otherwise between or among the Issuer and any Restricted Subsidiaries not prohibited by this Indenture, and guarantees of Indebtedness of any other Person (other than the Issuer or any Restricted Subsidiary) that are otherwise not prohibited by this Indenture; and

(2) any Restricted Subsidiary of the Issuer that (i) is the direct or indirect owner of all or a majority (including together with one or more other Non-Recourse Subsidiaries) of the Equity Interests in one or more Persons, each of which meets the qualifications set forth in clause (1) of this definition, (ii) has no Subsidiaries other than Subsidiaries each of which meets the conditions set forth in clause (1) or clause (2)(i) of this definition, (iii) owns no material businesses or assets other than those businesses and assets reasonably necessary, appropriate or desirable for, or reasonably related or ancillary to, no more than one individual Project or other activities reasonably related or ancillary thereto, or

 

28


necessary, appropriate or desirable in connection therewith, and (iv) has no Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit then outstanding other than any Non-Recourse Financing, Indebtedness arising from Permitted Intercompany Activities or otherwise between or among the Issuer and any Restricted Subsidiaries not prohibited by this Indenture, and guarantees of Indebtedness of any other Person (other than the Issuer or any Restricted Subsidiary) that are otherwise not prohibited by this Indenture.

As of the Issue Date, each of Venture Global Calcasieu Pass Holding, LLC, Calcasieu Pass Funding, LLC, Calcasieu Pass Holdings, LLC, Calcasieu Pass Pledgor, LLC, Venture Global Calcasieu Pass, LLC, TransCameron Pipeline, LLC, Calcasieu Tug Services, LLC, Calcasieu Pass Operations, LLC, TransCameron Operations, LLC, Venture Global CCS Cameron, LLC, Venture Global Plaquemines LNG Holding II, LLC, Venture Global Plaquemines LNG Holding, LLC, Plaquemines LNG Funding, LLC, Plaquemines LNG Holdings Pledgor, LLC, Plaquemines LNG Holdings, LLC, Plaquemines LNG Pledgor, LLC, Venture Global Plaquemines LNG, LLC, Venture Global Gator Express, LLC, Plaquemines Tug Services, LLC, Plaquemines LNG Operations, LLC, Venture Global CCS Plaquemines, LLC, Gator Express Operations, LLC, Venture Global CP2 LNG Holding, LLC, Venture Global CP2 LNG, LLC, Venture Global CP Express, LLC, Venture Global Delta LNG, LLC, Venture Global Delta Express, LLC, Venture Global Midstream Holdings, LLC, VG LNG Shipping, LLC, CP2 LNG Operations, LLC, CP Express Operations, LLC, Cameron Generation, LLC, Plaquemines Generation, LLC, Venture Global Ship Management Ltd., Venture Global Shipping Holdings, LLC, Venture Global Shipping I, LLC, Venture Global Shipping II, LLC, Venture Global Shipping III, LLC, Venture Global Shipping IV, LLC and Venture Global Shipping V, LLC, shall constitute Non-Recourse Subsidiaries.

“Non-U.S. Person” means a Person who is not a U.S. Person.

Note Documents” means this Indenture (including any Guarantee), the Notes and the Security Documents.

Note Obligations” means all obligations of the Issuer and the Guarantors under the Note Documents.

Notes” means the Initial Notes and any Additional Notes. Unless the context requires otherwise, all references to “Notes” for all purposes of this Indenture shall include any Additional Notes that are actually issued and authenticated. The Initial Notes of any series and all Additional Notes of such series shall be treated as a single class for all purposes under this Indenture, and unless the context otherwise requires, all references to the Notes of any series shall include the Initial Notes and any Additional Notes of such series.

Notes Parties” means, collectively, the Trustee, the Agents, each other agent, and the Holders, in each case, under this Indenture and the Collateral Agent under the Collateral Agency Agreement.

 

29


Offering Memorandum” means the Issuer’s final offering memorandum dated October 19, 2023 relating to the sale of the Initial Notes.

Officer” means, with respect to any Person, the Chairman of the Board of Directors, the Chief Executive Officer, the President, the Chief Operating Officer, the Chief Financial Officer, the Treasurer, any Assistant Treasurer, the Controller, the Secretary or any Vice-President of such Person.

Officer’s Certificate” means a certificate which meets the requirements set forth in Section 13.02 and Section 13.03, and which is signed by an Officer of the Issuer, a Guarantor or any successor Person to the Issuer or any Guarantor, as the case may be, and delivered to the Trustee.

Opinion of Counsel” means an opinion or opinions from legal counsel which opinion is reasonably acceptable to the Trustee and meets the requirements of Section 13.02 and Section 13.03. The counsel may be an employee of, or counsel to, the Issuer, any Subsidiary of the Issuer or the Trustee.

Parent Entity” means the Issuer and any Person that is the direct or indirect parent of the Issuer and of which the Issuer is a direct or indirect Subsidiary.

Participant” means, with respect to the Depositary, Euroclear or Clearstream, a Person who has an account with the Depositary, Euroclear or Clearstream, respectively (and, with respect to DTC, shall include Euroclear and Clearstream).

Permitted Business” means (a)(i) any businesses, services or activities engaged in by the Issuer or any of its Subsidiaries on the Issue Date, (ii) any Project, and any businesses, services or activities engaged in by the Issuer or any of its Subsidiaries in connection with any Project, including in connection with preparing for, and implementing any Project, and (iii) any businesses, services and activities engaged in by the Issuer or any of its Subsidiaries that are reasonably related, complementary, incidental, synergistic, ancillary or similar to any of the foregoing or are, in whole or in part, extensions, expansions or developments of any thereof, and (b) where the context requires, any Person engaged primarily in the businesses, services or activities described in clause (a) of this definition, in each case, as determined by the Issuer in good faith.

Permitted Business Investments” means Investments by the Issuer or any of its Restricted Subsidiaries in any Person (including any Joint Venture or Unrestricted Subsidiary); provided that:

(1) such Person is engaged in a Permitted Business;

(2) except in the case of any such Investment by a Non-Recourse Subsidiary, at the time of such Investment and immediately thereafter, the Issuer could incur $1.00 of additional Indebtedness under the Holdco Debt Ratio test set forth in Section 4.09(a); and

(3) if, upon consummation of such Investment, such Person will be a Restricted Subsidiary, then if either such Restricted Subsidiary will be a Recourse Person and has outstanding any Indebtedness, or such Person will be a Non-Recourse Subsidiary and has outstanding Indebtedness at the time of such Investment that is recourse to any Recourse Person, then in each case such Person could, at the time such Investment is made, incur such Indebtedness at such time pursuant to Section 4.09.

 

30


Permitted Holder” means (a) the Investors and (b) any Person with which one or more Investors form a “group” (within the meaning of Section 14(d) of the Exchange Act as in effect on the date of this Indenture) so long as, in the case of this clause (b), such one or more Investors directly or indirectly collectively Beneficially Own more than 50% of the aggregate voting Equity Interests that are Beneficially Owned by the group.

Permitted Intercompany Activities” means any transactions between or among the Issuer and its Restricted Subsidiaries that are entered into in the ordinary course of business, consistent with past practice or industry norms, or that are reasonably necessary, appropriate or advisable in connection with the ownership or operation of the business of the Issuer and its Restricted Subsidiaries, including, but not limited to, (i) payroll, cash management, netting, overdraft protection, purchasing, insurance and hedging arrangements; (ii) management, technology and licensing arrangements; and (iii) marketing and other professional services and shipping and maintenance arrangements.

Permitted Investment” means:

(1) any Investment in the Issuer or any Restricted Subsidiary;

(2) any Investment in a Person, if as a result of such Investment:

(i) such Person becomes a Restricted Subsidiary; or

(ii) such Person is merged, consolidated or amalgamated with or into, or transfers all or substantially all of its assets to, or is liquidated into, the Issuer or a Restricted Subsidiary, and in each case, any Investment held by any such Person; provided that such Investment was not made by such Person in contemplation of such Person becoming a Restricted Subsidiary or such merger, consolidation, amalgamation, transfer or liquidation;

(3) any Investment in cash or Cash Equivalents;

(4) any Investment made as a result of the receipt of non-cash consideration from an Asset Sale that was made pursuant to and in compliance with Section 4.10 or any other disposition of assets not constituting an Asset Sale;

(5) any Investment existing on the Issue Date and any extension, modification or renewal of any such Investments (but not any such extension, modification or renewal to the extent it involves additional advances, contributions or other investments of cash or property, except as otherwise permitted under this Indenture);

(6) (a) any acquisition of assets solely in exchange for the issuance of Equity Interests (other than Disqualified Stock) of the Issuer and (b) advances and prepayments for asset purchases (i) in the ordinary course of business or (ii) if such asset purchases would otherwise constitute a Permitted Investment;

 

31


(7) (i) extensions of trade credit (or notes receivable arising from such grant) and deposits, prepayments and other credits to suppliers made in the ordinary course of business, and Investments received in compromise or resolution thereof from financially troubled account debtors or in connection with the bankruptcy or reorganization of suppliers or customers or in settlement of delinquent obligations of, or other disputes with, suppliers and customers, and other credits to suppliers in the ordinary course of business, or (ii) any Investments received in compromise or resolution of litigation, arbitration or other disputes;

(8) Hedging Obligations permitted under Section 4.09(b)(13);

(9) (i) Investments in the Notes, including repurchases of the Notes, and (ii) Investments in the Existing Notes, including repurchases of the Existing Notes;

(10) any Investment in prepaid expenses, negotiable instruments held for collection and lease, utility, workers’ compensation and performance and other similar deposits;

(11) Management Advances;

(12) Permitted Business Investments; provided, however, that if any Investment pursuant to this clause (12) is made in any Person that is not a Restricted Subsidiary of the Issuer at the date of the making of such Investment and such Person becomes a Restricted Subsidiary after such date, such Investment shall thereafter be deemed to have been made pursuant to clause (1) above and shall cease to have been made pursuant to this clause (12);

(13) (i) any guarantee of Indebtedness permitted to be incurred pursuant to Section 4.09, (ii) any guarantee of performance obligations in the ordinary course of business, and (iii) the creation of Liens on the assets of the Issuer or any Restricted Subsidiary in compliance with Section 4.12;

(14) Investments consisting of the licensing or contribution of intellectual property pursuant to joint marketing arrangements with other Persons;

(15) extensions of credit to (and guarantees to the benefit of) customers, suppliers, vendors, contractors and service providers in the ordinary course of business including, advances to customers and suppliers that are recorded as accounts receivable, prepaid expenses or deposits on the balance sheet of the Issuer and its Restricted Subsidiaries in the ordinary course of business;

(16) other Investments made since the Issue Date in any Person having an aggregate Fair Market Value that are at that time outstanding (measured, with respect to each Investment, on the date such Investment was made and without giving effect to subsequent changes in value) not to exceed the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period; provided that if any Investment pursuant to this clause (16) is made in any Person that is not a Restricted Subsidiary of the Issuer at the date of the making of such Investment and such Person becomes a Restricted Subsidiary of the Issuer after such date, such Investment shall thereafter be deemed to have been made pursuant to clause (1) above and not this clause (16);

 

32


(17) acquisitions or other Investments consisting of assets, equipment, inventory, supplies, materials and property intended for use in any Project;

(18) payroll, travel and similar advances to cover matters that are expected at the time of such advances ultimately to be treated as expenses for accounting purposes and that are made in the ordinary course of business;

(19) trade receivables and prepaid expenses, in each case arising in the ordinary course of business; provided that such receivables and prepaid expenses would be recorded as assets in accordance with GAAP;

(20) earnest money deposits may be made to the extent required in connection with acquisitions permitted under this Indenture or the acquisition or real property and related assets;

(21) Investments by the Issuer or any Restricted Subsidiary consisting of deposits, prepayment and other credits to suppliers or landlords made in the ordinary course of business;

(22) Investments in certificates of deposit, banker’s acceptances and time deposits maturing within one year from the date of acquisition thereof issued or guaranteed by or placed with, and money market deposit accounts issued or offered by, any domestic office of any commercial bank that has a combined capital and surplus and undivided profits of not less than $500.0 million;

(23) Investments pursuant to any Project Obligations, any Permitted Project Undertaking or any Permitted Transaction;

(24) [reserved];

(25) Investments the payment for which consists of Equity Interests (other than Disqualified Stock, except to the extent issued by the Issuer to one of its Restricted Subsidiaries) of the Issuer, or redemptions in whole or in part of any of the Equity Interests of the Issuer (other than Disqualified Stock, except to the extent issued by the Issuer to one of its Restricted Subsidiaries) or with the proceeds from substantially concurrent equity contributions or new Equity Interests (and in no event shall such contribution or issuance so utilized increase the amount available as Incremental Funds for Restricted Payments pursuant to Section 4.07(a) or be duplicative of any payments pursuant to Section 4.07(b)(2)) (other than Disqualified Stock, except to the extent issued by the Issuer to one of its Restricted Subsidiaries);

(26) any transaction to the extent it constitutes an Investment that is permitted by and made in accordance with Section 4.11(b) (except transactions described in clauses (2), (7), (11) and (14) of Section 4.11(b);

 

33


(27) any Investment by any Captive Insurance Subsidiary in connection with the provision of insurance to the Issuer or any of its Subsidiaries, which Investment is made in the ordinary course of business or consistent with past practice or industry norms of such Captive Insurance Subsidiary, or by reason of applicable law, rule, regulation or order, or that is required or approved by any regulatory authority having jurisdiction over such Captive Insurance Subsidiary or its business, as applicable;

(28) Investments in connection with any Permitted Intercompany Activities and, to the extent deemed reasonably necessary by the Issuer in good faith for the consummation of, any IPO Reorganization Transaction or any Tax Restructuring;

(29) guarantees of leases or other obligations that do not constitute Indebtedness, in each case, entered into in the ordinary course of business or consistent with past practice or industry norms;

(30) Investments in or relating to a Receivables Subsidiary that, in the good faith determination of Issuer are necessary or advisable to effect any Permitted Receivables Financing (including any contribution of replacement or substitute assets to such subsidiary) or any repurchase obligation in connection therewith;

(31) Investments in connection with any Permitted Receivables Financing permitted under this Indenture, the contribution, sale or other transfer of Permitted Receivables Financing Assets, cash or Cash Equivalents made in connection with a Permitted Receivables Financing permitted under this Indenture or repurchases in connection with the foregoing (including the contribution or lending of cash and Cash Equivalents to Subsidiaries to finance the purchase of receivables or related assets from the Issuer or any Restricted Subsidiary or to otherwise fund required reserves, the contribution of replacement or substitute assets to a Receivables Subsidiary and Investments of funds held in accounts permitted or required by the arrangements governing such Permitted Receivables Financing or any related Indebtedness); and

(32) Investments in Joint Ventures having an aggregate fair market value taken together with all other Investments made pursuant to this clause (32) that are at that time outstanding not to exceed the greater of (A) $500 million and (B) 15.0% of Distributable Cash for the applicable Test Period (in each case, determined on the date such Investment is made, with the fair market value of each Investment being measured at the time made and without giving effect to subsequent changes in value), plus the amount of any returns (including dividends, payments, interest, distributions, returns of principal, profits on sale, repayments, income and similar amounts) in respect of such investments; provided, however, that if any Investment pursuant to this clause (32) is made in any Person that is not a Restricted Subsidiary of the Issuer at the date of the making of such Investment and such Person becomes a Restricted Subsidiary after such date, such Investment shall thereafter be deemed to have been made pursuant to clause (1) above and shall cease to have been made pursuant to this clause (32).

 

34


For purposes of determining compliance with this definition, in the event that a proposed Investment (or a portion thereof) meets the criteria of clauses (1) through (32) above, the Issuer will be entitled to divide or classify or later divide or reclassify (based on circumstances existing on the date of such reclassification) such Investment (or a portion thereof) between such clauses (1) through (32) in any manner that otherwise complies with this definition.

Permitted Liens” means:

(1) Liens securing Indebtedness (i) under Credit Facilities incurred pursuant to Section 4.09(b)(1) or (ii) incurred pursuant to the Holdco Debt Ratio test set forth Section 4.09(a); provided, however, that no such Liens may be created upon any asset or property that is not Collateral unless the Notes (or a Guarantee, in the case of a Lien on assets or property of a Guarantor) are equally and ratably secured with, or prior to, such Indebtedness so long as such Indebtedness is so secured (except that Liens securing subordinated Indebtedness shall be expressly subordinate to any Lien securing the Notes to at least the same extent such subordinated Indebtedness is subordinate to the Notes or such Guarantee, as the case may be);

(2) Liens on property (including Capital Stock) of a Person existing at the time such Person becomes a Restricted Subsidiary or is merged with or into or consolidated with the Issuer or any of its Restricted Subsidiaries; provided that such Liens were in existence prior to the contemplation of such Person becoming a Restricted Subsidiary or such merger or consolidation, were not incurred in contemplation thereof and do not extend to any assets other than those of the Person that becomes a Restricted Subsidiary or is merged with or into or consolidated with the Issuer or any Restricted Subsidiary;

(3) Liens on property existing at the time the Issuer or any of its Restricted Subsidiaries acquires such property; provided that such Liens were in existence prior to the contemplation of such acquisition, were not incurred in contemplation thereof and do not extend to any other assets of the Issuer or any of its Restricted Subsidiary;

(4) Liens securing Indebtedness under Bank Product Obligations, cash pooling arrangements and Hedging Obligations, which obligations are permitted by Section 4.09(b)(13) and Liens securing or arising by reason of any netting or set-off arrangement entered into in the ordinary course of banking or other trading activities;

(5) (i) Liens existing on the Issue Date and (ii) any Liens securing the Existing Notes and the related guarantees thereof;

(6) Liens in favor of the Issuer or any of its Restricted Subsidiaries;

(7) Liens for Taxes, statutory Liens of landlords, banks (and rights of set-off), of carriers, warehousemen, mechanics, repairmen, workmen and materialmen, and other Liens imposed by law;

(8) Liens incurred in the ordinary course of business in connection with workers’ compensation, unemployment insurance and other types of social security, or pledges or deposits to secure the performance of tenders, statutory obligations, surety and appeal bonds, bids, leases, concessions, government contracts, trade contracts, performance and return-of-money bonds and other similar or related obligations (exclusive of obligations for the payment of borrowed money or other Indebtedness);

 

35


(9) Liens relating to current or future escrow arrangements securing Indebtedness of the Issuer or any Guarantor (including, without limitation, arrangements for the escrow of the proceeds of Indebtedness pending consummation of an acquisition);

(10) Liens on the Capital Stock or any assets or properties of, or advances or loans to, Non-Recourse Subsidiaries (i) either securing any Non-Recourse Financing or any Project Obligations of one or more Non-Recourse Subsidiaries or (ii) or permitted pursuant to the terms thereof or by a waiver of such terms;

(11) any other Liens securing Indebtedness permitted under clauses (4), (7), (17), (18), (22), (23) or (24) of Section 4.09(b); provided that (i) Liens securing obligations relating to any Indebtedness, Disqualified Stock or Preferred Stock to be incurred pursuant to Section 4.09(b)(4) extend only to the assets so purchased, leased, developed, expanded, constructed, installed, replaced, repaired, refurbished, repositioned or improved or subject to such Sale and Leaseback (plus improvements, accessions, proceeds or dividends or distributions in respect thereof, or replacements of any thereof); provided, further, that individual financings of assets provided by one lender or group of lenders may be cross-collateralized to other financings of assets by such lender or group of lenders; (ii) Liens securing obligations relating to any Indebtedness permitted to be incurred pursuant to Section 4.09(b)(24) relate only to obligations relating to Refinancing Indebtedness that is secured by Liens on all or a portion of the same assets or the same categories or types of assets as the assets (plus improvements, accessions, proceeds or dividends or distributions in respect thereof, or replacements of any thereof) that secured (or, under the written arrangements under which the original Lien arose, could secure) the Indebtedness being refinanced; and (iii) Liens securing Indebtedness permitted to be incurred pursuant to clause (y) of Section 4.09(b)(7) shall only be permitted if such Liens are limited to all or a part of the same property or assets, including Capital Stock, acquired (plus improvements, accessions, proceeds or dividends or distributions in respect thereof, or replacements or any thereof), or of a Person acquired or merged, amalgamated or consolidated with or into the Issuer or any Restricted Subsidiary, in any transaction to which such Indebtedness relates and such Indebtedness was not incurred in contemplation of such transaction;

(12) Liens granted in favor of a Governmental Authority, including any decommissioning obligations, by a Non-Recourse Subsidiary when required by such Governmental Authority in connection with the operations of such Non-Recourse Subsidiary in the ordinary course of its business;

(13) Liens on any property or assets of any Non-Recourse Subsidiary arising out of conditional sale, title retention, hire purchase, consignment or similar arrangements for the sale or purchase of goods entered into in the ordinary course of business or consistent with past practice or industry norms;

 

36


(14) any interest or title of a lessor or sublessor under any lease or sublease of real estate permitted hereunder (or with respect to any deposits or reserves posted thereunder);

(15) Liens solely on any cash earnest money deposits made by the Issuer or any of its Restricted Subsidiaries in connection with any letter of intent or purchase agreement permitted hereunder;

(16) purported Liens evidenced by the filing of precautionary UCC financing statements relating solely to (i) operating leases of personal property entered into in the ordinary course of business, (ii) the sale of accounts receivable and/or (iii) the sale of Permitted Receivables Financing Assets and related assets in connection with any Permitted Receivables Financing;

(17) Liens in favor of customs and revenue authorities arising as a matter of law to secure payment of customs duties in connection with the importation of goods;

(18) any zoning or similar law or right reserved to or vested in any governmental office or agency to control or regulate the use of any real property;

(19) non-exclusive outbound licenses of patents, copyrights, trademarks and other intellectual property rights granted by the Issuer or any of its Restricted Subsidiaries in the ordinary course of business and not interfering in any respect with the ordinary conduct of or materially detracting from the value of the business of the Issuer or such Restricted Subsidiary;

(20) Liens given to a public authority or other service provider or any other Governmental Authority when required by such public authority or other service provider or other Governmental Authority in connection with the operations of such person in the ordinary course of business;

(21) any agreement (or provisions therein) to lease, option to lease, license, sub-lease or other right to occupancy assumed or entered by or on behalf of the Issuer or any Restricted Subsidiary in the ordinary course of its business;

(22) reservations, limitations, provisos and conditions, if any, expressed in any grants, permits, licenses or approvals from any Governmental Authority or any similar authority;

(23) Liens in the nature of restrictions on changes in the direct or indirect ownership or control of any Non-Recourse Subsidiary;

(24) Liens in the nature of rights of first refusal, rights of first offer, purchase options and similar rights in respect of the Equity Interests or assets of Non-Recourse Subsidiaries included in documentation evidencing contemplated purchase and sale transactions permitted under this Indenture, any Non-Recourse Financing or any Project Obligations;

 

37


(25) Liens securing insurance premium financing arrangements;

(26) Liens in favor of credit card companies pursuant to agreements therewith;

(27) Liens on real estate in connection with the financing of the acquisition or development thereof; provided that facilities are or will be located on such property or assets primarily for the use of the Issuer or any of its Subsidiaries;

(28) [reserved];

(29) Liens on assets pursuant to merger agreements, stock or asset purchase agreements and similar agreements in respect of the disposition of such assets;

(30) minor survey exceptions, minor encumbrances, minor defects or irregularities in title, easements or reservations of, or rights of others for, licenses, rights of way, servitudes, access rights, sewers, electric lines, open space and conservation easements, railways, water, drainage, gas and oil pipelines, light, power, internet or cable television services, telegraph and telephone lines, other utilities and other similar purposes, or zoning or other restrictions as to the use of real property, not interfering in any material respect with the conduct of the business of the Issuer and its Restricted Subsidiaries;

(31) Liens deemed to exist in connection with repurchase agreements and other similar Investments to the extent such Investments are permitted under this Indenture;

(32) Liens on the Capital Stock of any Unrestricted Subsidiary or Joint Venture to secure Indebtedness of such Unrestricted Subsidiary or Joint Venture;

(33) Liens securing Indebtedness in an aggregate principal amount not to exceed, as of the date of incurrence of such Lien or Indebtedness secured thereby, the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

(34) Liens created by or resulting from any litigation or other proceedings or resulting from operation of law with respect to any attachment, judgments, writs, awards, warrants, orders or similar Liens to the extent that such litigation, other proceedings, attachments, judgments, writs, awards, warrants or orders do not cause or constitute an Event of Default;

(35) Liens securing any security given to a public authority or other service provider or any other Governmental Authority when required by such utility or other Governmental Authority in connection with the operations of such person in the ordinary course of its business;

(36) Liens securing the Notes issued on the Issue Date (excluding, for the avoidance of doubt, Liens securing any Additional Notes) and the related Guarantees;

(37) Liens on property or assets of any Non-Recourse Subsidiary under construction (and related rights) in favor of a contractor or developer or arising from progress or partial payments by a third party relating to such property or assets;

 

38


(38) Liens on vehicles or equipment of any Non-Recourse Subsidiary in the ordinary course of business or consistent with past practice or industry norms;

(39) Liens securing Indebtedness of Recourse Persons permitted under Section 4.09; provided that such Liens are secured by Collateral and junior in priority to the Liens securing the Notes;

(40) Liens on assets securing any Indebtedness owed to any Captive Insurance Subsidiary by the Issuer or any Restricted Subsidiary;

(41) Liens securing any Project Obligations, Permitted Project Undertakings or any Permitted Transactions;

(42) Liens existing, or deemed to exist, in connection with the sale or transfer of any assets in a transaction not prohibited under this Indenture, customary rights and restrictions contained in agreements relating to such sale or transfer pending the completion thereof; and

(43) Liens (i) on accounts receivable, royalty or other revenue streams and other rights to payment and any other assets incurred in connection with a Permitted Receivables Financing, (ii) in connection with bankers’ acceptances, discounted bills of exchange or the discounting or factoring of receivables for credit management purposes, in each case incurred or undertaken in the ordinary course of business, (iii) on Permitted Receivables Financing Assets or Liens on other assets granted pursuant to Standard Securitization Undertakings, in each case, incurred in connection with Permitted Receivables Financings permitted under this Indenture and (iv) securing Refinancing Indebtedness of the foregoing.

For purposes of this definition, the term “Indebtedness” shall be deemed to include interest on such Indebtedness. In the event that a Permitted Lien meets the criteria of more than one of the types of Permitted Liens (at the time of incurrence or at a later date), the Issuer in its sole discretion may divide, classify or from time to time reclassify all or any portion of such Permitted Lien in any manner that complies with this Indenture and such Permitted Lien shall be treated as having been made pursuant only to the clause or clauses of the definition of Permitted Lien to which such Permitted Lien has been classified or reclassified.

Permitted Project Undertaking” means, as to any Person, any guarantee or other credit support provided by such Person (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness), or any payment, performance or other obligation in respect of which such Person or is directly or indirectly liable (as a guaranteeing person or otherwise) or has granted a Lien on any of its assets as security (or has any obligation, contingent or otherwise, to do so), in each case, pursuant to any Project Obligation or otherwise arising in connection with any Project Document, any Project or any Permitted Business Investment (whether in favor or vendors, suppliers, contractors, customers, clients or otherwise), in each case excluding any Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations and debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit. For the avoidance of doubt, any guarantee to be issued by any Recourse Person in favor of Baker Hughes Energy Services LLC in respect of any Purchase Order for Liquefaction Train System equipment or for Power Island System equipment in connection with any Project shall be a “Permitted Project Undertaking.”

 

39


Permitted Receivables Financing” means any securitization or other similar financing (including any factoring program) of Permitted Receivables Financing Assets that is non-recourse to the Issuer and its Restricted Subsidiaries (except for any customary limited recourse pursuant to the Standard Securitization Undertakings), and in each case, reasonable extensions thereof.

Permitted Receivables Financing Assets” means (a) any accounts receivable, loan receivables, mortgage receivables, receivables or loans relating to the financing of insurance premiums, royalty, patent or other revenue streams and other rights to payment or related assets and the proceeds thereof and (b) all assets securing or related to any such receivable or asset, all contracts and contract rights, guarantees or other obligations in respect of any such receivable or asset, lockbox accounts and records with respect to any such receivable or assets and any other assets (including inventory and proceeds thereof) customarily transferred (or in respect of which security interests are customarily granted) together with receivables or assets in connection with a securitization, factoring or receivables financing or sale transaction.

Permitted Transactions” means any of the following: (a) any Equity Financing Transaction, (b) any ECR Transaction, and (c) any prepayment, redemption, purchase, repurchase, or defeasance of all or part of any Equity Interests issued in connection with (including any Stonepeak Equity Interests), or that are the subject of, any Equity Financing Transaction or ECR Transaction.

Permitted Transferees” means, with respect to any Person that is a natural Person (and any Permitted Transferee of such Person), (a) such Person’s Immediate Family Members and (b) such Person’s estate, heirs, legatees, distributees, executors and/or administrators upon the death of such Person, or any private foundation or fund that is controlled thereby, and any other Person who was an Affiliate of such Person upon the death of such Person and who, upon such death, directly or indirectly owned Equity Interests in the Issuer or any Parent Entity.

Person” means any individual, corporation, limited liability company, partnership, joint venture, association, joint-stock company, trust, unincorporated organization or other business entity or any government or any agency or political subdivision thereof.

Pledged Equity” means, with respect to the Issuer or any Guarantor, the shares of Capital Stock of any other Person in which the Issuer or such Guarantor, as applicable, has granted a security interest to the Collateral Agent, for the benefit of the Notes Parties, pursuant to the Security Agreement, together with any other shares, stock or partnership unit certificates, options or rights of any nature whatsoever in respect of such Capital Stock that may be issued or granted to, or held by, the Issuer or such Guarantor.

Preferred Equity” or “Preferred Stock” means any Equity Interest with preferential rights of payment of dividends or upon liquidation, dissolution, or winding up.

 

40


Private Placement Legend” means the legend set forth in Section 2.06(g)(1) to be placed on all Notes issued under this Indenture, except where otherwise permitted by the provisions of this Indenture.

Project” means each of the following:

(1) any individual natural gas liquefaction and export project, together with any other businesses or assets (other than any other separate natural gas liquefaction and export project) that are reasonably related, complementary, incidental, synergistic or ancillary to such project or are, in whole or in part, extensions, expansions or developments of any thereof, as determined by the Issuer in good faith; and

(2) any one or more assets, facilities or projects in the energy industry, including natural gas pipelines, natural gas shipping assets (including liquefied natural gas carriers, tugs and floating storage units), natural gas gathering and processing projects, upstream gas projects, re-gasification projects, carbon capture and sequestration projects, in each case, together with any other businesses or assets that are reasonably related, ancillary or similar to any of the foregoing or are, in whole or in part, extensions, expansions or developments of any thereof, as determined by the Issuer in good faith.

For the avoidance of doubt, an individual “Project” for purposes of this Indenture may include any one or more of the foregoing (either alone or in combination), in each case to the extent they are reasonably related, complementary, incidental, synergistic, ancillary or similar, and any extensions, expansions or developments of any thereof (as determined by the Issuer in good faith), and still be deemed to be an individual Project for purposes of this Indenture, except that an individual Project may not include more than one individual natural gas liquefaction and export project.

Project Company” means any Restricted Subsidiary of the Issuer that (i) is the owner, lessor and/or operator of (or is formed to own, lease or operate) any Project, (ii) is the lessee, borrower, issuer or seller (or is formed to be the lessee, borrower, issuer or seller) in respect of any financing transaction entered into in connection with any Project, including any Non-Recourse Financing, Equity Financing Transaction, ECR Transaction or Sale and Leaseback Transaction, (iii) develops or constructs (or is formed to develop or construct) any Project, (iv) engages in, conducts or facilitates (or is formed to engage in, conduct or facilitate) any activities reasonably related or ancillary any activities described in clauses (i), (ii) and (iii) of this definition, and/or (v) any combination of the foregoing, in each case as determined by the Issuer in good faith.

Project Costs” means any and all costs of evaluating, acquiring, leasing, designing, engineering, procuring, purchasing, developing, constructing and operating a Project, including all costs incurred in connection with preparing for and implementing, optioning, permitting, insuring, constructing, installing, commissioning, financing (including pursuant to any Non-Recourse Financing, Equity Financing Transaction, ECR Transaction or Sale and Leaseback Transaction, and including interest, dividends and other amounts incurred or payable with respect thereto during construction, debt service and other reserves and the cost of any associated letters of credit and other credit support or equity backstop arrangements), testing and starting-up (including costs relating to all equipment, materials, spare parts and labor), in each case, whether incurred before or after the final investment decision with respect to such Project.

 

41


Project Document” means each contract, agreement, instrument or other written undertaking entered into by a Project Company in connection with the engineering, procurement, construction, testing, commissioning, completion, insuring, operation, maintenance or repair of a Project.

Project Obligations” means as to any Person, any Contractual Obligation under any Project Document or otherwise entered into or arising in connection with any Project Document, any Project, or with respect to any Project Costs, in each case excluding any Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations and debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit.

QIB” means a “qualified institutional buyer” as defined in Rule 144A.

Rating Agency” means any of the following: (a) S&P Global Ratings, a division of S&P Global Inc. (“S&P”); (b) Moody’s Investors Service, Inc. (“Moody’s”); or (c) Fitch Ratings, Inc. (“Fitch”), and, in each case, their respective successors.

Rating Decline” means, with respect to any series of Notes and in connection with any Change of Control, the occurrence of:

(1) during the occurrence and continuance of any period in which such Notes have two or more (or, if only one of the following ratings agencies is at the applicable time providing a rating for such Notes, one) ratings equal to or greater than (x) Baa3 by Moody’s, (y) BBB- by S&P and (z) BBB- by Fitch (or, if all of such entities cease to provide such ratings, the equivalent rating from any other “nationally recognized statistical rating organization” registered with the Commission) (such period, an “Investment Grade Period”), a ratings downgrade which results in such Notes no longer having two (or, if only one of the preceding ratings agencies is at the time providing a rating for such Notes, one) such ratings of at least BBB- or Baa3, as applicable; or

(2) during any period which is not an Investment Grade Period, a ratings downgrade of such Notes by any two (or, if only one of the following ratings agencies is at the time providing a rating for such Notes, one) of (x) Moody’s, (y) S&P and (z) Fitch (or, if all of such entities cease to provide such ratings, the equivalent rating from any other “nationally recognized statistical rating organization” registered with the Commission);

provided, however, that in each case such downgrade occurs on, or within 90 days after the earlier of (a) such Change of Control, (b) the date of public notice of the occurrence of such Change of Control, or (c) public notice of the intention by the Issuer to effect such Change of Control (which period shall be extended so long as the rating of the Issuer is under publicly announced consideration for downgrade by any Rating Agency); and provided further, that a Rating Decline otherwise arising by virtue of a particular reduction in rating will not be deemed to have occurred in respect of a particular Change of Control (and thus will be disregarded in determining whether a Rating Decline has occurred for purposes of the definition of Change of Control Triggering Event) if the Rating Agencies making the reduction in rating do not announce or publicly confirm or inform the Issuer that the reduction was the result, in whole or in part, of any event or circumstance comprised of or arising as a result of, or in respect of, the applicable Change of Control (whether or not the applicable Change of Control has occurred at the time of the Rating Decline).

 

42


Receivables Subsidiary” means (i) any direct or indirect Subsidiary of any Restricted Subsidiary, whose organizational documents contain restrictions on its purpose and activities intended to preserve its separateness from such Restricted Subsidiary and/or one or more Subsidiaries of such Restricted Subsidiary, established in connection with a Permitted Receivables Financing and (ii) any Unrestricted Subsidiary involved in a Permitted Receivables Financing, which is not permitted by the terms of such Permitted Receivables Financing to guarantee the obligations under the Notes or provide Collateral.

Recourse Persons” means (a) the Issuer, (b) the Guarantors and (c) each other Restricted Subsidiary that is not a Non-Recourse Subsidiary.

Reference Date” means May 26, 2023, the date of first issuance of the Existing Notes. “Refinancing Indebtedness” means any Indebtedness that refinances any Indebtedness in compliance with Section 4.09; provided, however:

(1) such Refinancing Indebtedness has a stated maturity that is either: (i) no earlier than the stated maturity of the Indebtedness being refinanced; or (ii) after the final maturity date of each series of Notes then outstanding;

(2) such Refinancing Indebtedness has an average life at the time such Refinancing Indebtedness is incurred that is equal to or greater than the average life of the Indebtedness being refinanced;

(3) such Refinancing Indebtedness has an aggregate principal amount (or if issued with an original issue discount, an aggregate issue price) that is equal to or less than (i) the aggregate principal amount (or if incurred with original issue discount, the aggregate accreted value) then outstanding or committed under the Indebtedness being refinanced, plus (ii) an amount necessary to pay any fees and expenses (including original issue discount, upfront fees or similar fees) and premiums (including tender premiums) and accrued and unpaid interest, related to such modification, refinancing, refunding, extension, renewal or replacement;

(4) if the Indebtedness being refinanced is subordinated Indebtedness, such Refinancing Indebtedness has a final maturity date later than the final maturity date of each series of Notes then outstanding, and is subordinated in right of payment to the Notes on terms at least as favorable to the holders of Notes as those contained in the Indebtedness being refinanced; and

 

43


(5) if the Indebtedness being refinanced is a Non-Recourse Financing, such Refinancing Indebtedness is a Non-Recourse Financing incurred by one or more Non- Recourse Subsidiaries; provided, however, that Refinancing Indebtedness shall not include Indebtedness of (i) the Issuer or a Restricted Subsidiary that refinances Indebtedness of an Unrestricted Subsidiary or a Joint Venture, (ii) the Issuer or a Guarantor that refinances Indebtedness of a Restricted Subsidiary that is not a Guarantor or (iii) a Recourse Person that refinances Indebtedness of a Non-Recourse Subsidiary.

Regulation S” means Regulation S promulgated under the Securities Act.

Regulation S Global Note” means a Regulation S Temporary Global Note or Regulation S Permanent Global Note, as appropriate.

Regulation S Permanent Global Note” means a permanent Global Note, substantially in the form of Exhibit A-1 or Exhibit A-2 hereto bearing the Global Note Legend and the Private Placement Legend and deposited with or on behalf of, and registered in the name of, the Depositary or its nominee, issued in a denomination equal to the outstanding principal amount of the Regulation S Temporary Global Note upon expiration of the applicable Restricted Period.

Regulation S Temporary Global Note” means a temporary Global Note, substantially in the form of Exhibit A-1 or Exhibit A-2 hereto bearing the Global Note Legend and the Private Placement Legend and the Regulation S Temporary Global Note Legend and deposited with or on behalf of, and registered in the name of, the Depositary or its nominee, issued in a denomination equal to the outstanding principal amount of the Notes initially sold in reliance on Rule 903.

Regulation S Temporary Global Note Legend” means the legend set forth in Section 2.06(g)(3) hereof.

Responsible Officer,” when used with respect to the Trustee, means any officer within the Corporate Trust Administration of the Trustee (or any successor group of the Trustee) or any other officer of the Trustee customarily performing functions similar to those performed by any of the above designated officers and also means, with respect to a particular corporate trust matter, any other officer to whom such matter is referred because of his knowledge of and familiarity with the particular subject.

Restricted Definitive Note” means a Definitive Note bearing, or that is required to bear, the Private Placement Legend.

Restricted Global Note” means a Global Note bearing, or that is required to bear, the Private Placement Legend.

Restricted Investment” means any Investment other than a Permitted Investment. “Restricted Period” means the 40-day distribution compliance period as defined in Regulation S.

Restricted Subsidiary” means any Subsidiary of the Issuer that is not an Unrestricted Subsidiary.

 

44


Retained Asset Sale Proceeds” means, at any date of determination, an amount determined on a cumulative basis of all Net Proceeds received by the Issuer or any of its Restricted Subsidiaries that, pursuant to application of the Asset Sale Prepayment Percentage, are or were not required to be applied pursuant to Section 4.10.

Rule 144” means Rule 144 promulgated under the Securities Act. “Rule 144A” means Rule 144A promulgated under the Securities Act.

Rule 144A Global Note” means a Global Note issued in accordance with Section 2.01(c). “Rule 903” means Rule 903 promulgated under the Securities Act.

Rule 904” means Rule 904 promulgated under the Securities Act.

Sale and Leaseback Transaction” means any arrangement providing for the leasing by the Issuer or any Restricted Subsidiaries of any real or tangible personal property, which property has been or is to be sold or transferred by the Issuer or such Restricted Subsidiary to a third Person in contemplation of such leasing.

Screened Affiliate” means any Affiliate of a Holder (i) that makes investment decisions independently from such Holder and any other Affiliate of such Holder that is not a Screened Affiliate, (ii) that has in place customary information screens between it and such Holder and any other Affiliate of such Holder that is not a Screened Affiliate and such screens prohibit the sharing of information with respect to the Issuer or its Subsidiaries, (iii) whose investment policies are not directed by such Holder or any other Affiliate of such Holder that is acting in concert with such Holder in connection with its investment in the Notes, and (iv) whose investment decisions are not influenced by the investment decisions of such Holder or any other Affiliate of such Holder that is acting in concert with such Holders in connection with its investment in the Notes.

Securities Act” means the Securities Act of 1933, as amended.

Security Agreement” means the Security Agreement dated as of May 26, 2023 among the Issuer, each other Grantor (as defined and referred to therein) and the Collateral Agent, as it may be amended, amended and restated, supplemented or otherwise modified from time to time.

Security Documents” means:

(1) the Security Agreement;

(2) the Collateral Agency Agreement;

(3) the Applicable Intercreditor Agreements, if any; and

(4) each of the security agreements, financing statements and other instruments executed and delivered by the Issuer or any Guarantor pursuant to this Indenture for purposes of providing collateral security or credit support for the Note Obligation; as the same may be amended, amended and restated, supplemented or otherwise modified or replaced from time to time.

 

45


Senior Class Debt Representative” means, with respect to this Indenture, the Trustee, and with respect to any Additional First Lien Debt Facility, the applicable Additional Agent that becomes a party to an Applicable Intercreditor Agreement.

Senior Indebtedness” means: (a) any Indebtedness of the Issuer that ranks equally in right of payment with the Notes; and (b) any Indebtedness of a Guarantor that ranks equally in right of payment to the Guarantee of such Guarantor.

series” means, with respect to any First Lien Obligations, each of (i) the Note Obligations, (ii) the obligations of the Issuer and guarantors, if any, with respect to the Existing Notes, the Existing Notes Indenture and the related guarantees, if any, and the Security Documents and (iii) the Additional First Lien Obligations incurred pursuant to any Additional First Lien Debt Facility or any related Additional First Lien Documents.

Short Derivative Instruments” means, as to any person, a Derivative Instrument (i) the value of which to such person generally decreases, and/or the payment or delivery obligations of such person under which generally increase, with positive changes in the financial performance and/or position of the Issuer and/or (ii) the value of which to such person generally increases, and/or the payment or delivery obligations of such person under which generally decrease, with negative changes in the financial performance and/or position of the Issuer.

Standard Securitization Undertakings” means all representations, warranties, covenants, pledges, transfers, purchases, dispositions, guaranties and indemnities (including repurchase obligations in the event of a breach of representation and warranty) and other undertakings made or provided, and servicing obligations undertaken, by any Restricted Subsidiary or Subsidiary thereof that the Issuer has determined in good faith to be customary in connection with a Permitted Receivables Financing.

Stated Maturity” means, with respect to any installment of interest or principal on any series of Indebtedness, the date on which the payment of interest or principal was scheduled to be paid in the documentation governing such Indebtedness as of the date of this Indenture, and will not include any contingent obligations to repay, redeem or repurchase any such interest or principal prior to the date originally scheduled for the payment thereof.

Stonepeak Equity Interests” means the Equity Interests of Calcasieu Pass Holdings, LLC and Calcasieu Pass Funding, LLC owned by Stonepeak Bayou Holdings LP and Stonepeak Bayou Holdings II LP, respectively.

Subsidiary” means, with respect to any specified Person:

(1) any corporation, association or other business entity of which more than 50% of the total voting power of shares of Capital Stock entitled (without regard to the occurrence of any contingency and after giving effect to any voting agreement or stockholders’ agreement that effectively transfers voting power) to vote in the election of directors, managers or trustees of the corporation, association or other business entity is at the time owned or controlled, directly or indirectly, by that Person or one or more of the other Subsidiaries of that Person (or a combination thereof);

 

46


(2) any partnership, joint venture, limited liability company or similar entity of which: more than 50% of the capital accounts, distribution rights, total equity and voting interests or general or limited partnership interests, as applicable, are owned or controlled, directly or indirectly, by such Person or one or more of the other Subsidiaries of that Person (or a combination thereof) whether in the form of membership, general, special or limited partnership or otherwise, and such Person or any Restricted Subsidiary of such Person is a controlling general partner or otherwise controls such entity; and

(3) any other entity, the management of which is controlled, directly or indirectly (whether by way of equity ownership or contractual arrangements or otherwise), by that Person or one or more of the other Subsidiaries of that Person (or a combination thereof) and the accounts of which would be consolidated with those of the Issuer in its consolidated financial statements as of such date prepared in accordance with GAAP.

Unless otherwise specified herein, a “Subsidiary” shall refer to a Subsidiary of the Issuer.

Tax” means all present or future taxes, levies, imposts, duties, assessments, charges, fees, deductions or withholdings (together with interest, penalties and other additions thereto) of any nature and whatever called, by whomsoever, on whomsoever and wherever imposed, levied, collected, withheld or assessed.

Tax Restructuring” means any reorganizations and other activities related to tax planning and tax reorganization (as determined by the Issuer in good faith) entered into after the Issue Date so long as such Tax Restructuring does not (1) materially impair (i) the ability of the Issuer and the Guarantors to make anticipated principal or interest payments on the Notes, (ii) any Guarantees or (iii) the security interests of the Collateral Agent on behalf of holders of the Notes, in each case, taken as a whole, or (2) cause material adverse Tax consequences to the holders of the Notes.

Test Period” means, with respect to any date of determination, the most recently ended four full consecutive fiscal quarters of the Issuer for which internal financial statements are available.

Test Revenue” means, for any period, the aggregate amount of net proceeds received by the Issuer and its Restricted Subsidiaries from sales generated by assets of any Project or Permitted Business prior to such assets being placed in service for accounting purposes in accordance with GAAP, and that are recognized as an offset to construction in progress on the balance sheet of the Issuer, determined on a consolidated basis in accordance with GAAP.

TIA” means the Trust Indenture Act of 1939, as amended (15 U.S.C. §§ 77aaa-77bbbb).

Treasury Rate” means, as of any redemption date, the yield to maturity as of the earlier of (a) such redemption date or (b) the date on which the Notes are defeased or satisfied and discharged, of United States Treasury securities with a constant maturity (as compiled and published in the most recent Federal Reserve Statistical Release H.15 (519) that has become publicly available at least two Business Days prior to the redemption date (or, if such Statistical Release is no longer

 

47


published, any publicly available source of similar market data)) most nearly equal to the period from the redemption date to, with respect to the 2029 Notes, November 1, 2028, and, with respect to the 2032 Notes, February 1, 2027; provided, however, that if such period is less than one year, the weekly average yield on actively traded United States Treasury securities adjusted to a constant maturity of one year will be used.

Trustee” means The Bank of New York Mellon Trust Company, N.A. until a successor replaces it in accordance with the applicable provisions of this Indenture and thereafter means the successor serving hereunder.

UCC” means the Uniform Commercial Code as in effect from time to time in any applicable jurisdiction.

Unrestricted Definitive Note” means a Definitive Note that does not bear and is not required to bear the Private Placement Legend.

Unrestricted Global Note” means a Global Note that does not bear and is not required to bear the Private Placement Legend.

Unrestricted Subsidiary” means:

(1) any Subsidiary of the Issuer that at the time of determination is an Unrestricted Subsidiary (as designated by the Board of Directors of the Issuer in accordance with Section 4.17);

(2) any Subsidiary of an Unrestricted Subsidiary; and

(3) as of the Issue Date, includes VG LNG Marketing, LLC, VG LNG Marketing Pte. Ltd., CPCD, LLC, Venture Global Controls, LLC, VG Aviation, LLC, Bayou Residential, LLC, and SQRD Holding LLC.

“U.S. dollars” or “$” means the lawful currency of the United States of America.

“U.S. Person” means a U.S. Person as defined in Rule 902(k) promulgated under the Securities Act.

VG Holdings” means Venture Global Holdings, Inc.

VGP Investor” means, collectively, (a) Venture Global Partners II, LLC and its Affiliates and (b) the funds, partnerships or other co-investment vehicles managed, advised or controlled by any Person referred to in the foregoing clause (a).

Voting Stock” of any specified Person as of any date means the Capital Stock of such Person that is at that time entitled to vote in the election of the Board of Directors (or comparable governing body) of such Person, measured by voting power rather than number of shares. For the avoidance of doubt, the sole managing member of a sole-member-managed limited liability company owns 100% of the Voting Stock of such limited liability company and the sole general partner of a limited partnership owns 100% of the Voting Stock of the limited partnership.

 

48


Wholly-Owned Subsidiary” means, with respect to any specified Person, a direct or indirect Subsidiary of such Person, 100% of the outstanding Capital Stock or other ownership interests of which (other than directors’ qualifying shares) is at the time owned by such Person or by one or more Wholly-Owned Subsidiaries of such Person.

Section 1.02 Other Definitions.

 

Term

   Defined in
Section

“Advance Offer”

   4.10(d)

“Advance Portion”

   4.10(d)

“Affiliate Transaction”

   4.11(a)

“Applicable Tax Laws”

   13.12

“Asset Sale Offer”

   4.10(d)

“Authentication Order”

   2.02

“Change of Control Offer”

   4.15(a)

“Change of Control Payment”

   4.15(b)

“Change of Control Payment Date”

   4.15(b)

“Collateral Advance Offer”

   4.10(c)

“Collateral Advance Portion”

   4.10(c)

“Collateral Asset Sale Offer”

   4.10(c)

“Collateral Excess Proceeds”

   4.10(c)

“Court Determination”

   6.02

“Covenant Defeasance”

   8.03

“Covenant Suspension Event”

   4.18(b)

“Declined Collateral Excess Proceeds”

   4.10(c)

“Declined Excess Proceeds”

   4.10(d)

“Declined Non-Collateral Excess Proceeds”

   4.10(d)

“Directing Holder”

   6.02

“DTC”

   2.03

“Event of Default”

   6.01

“Excess Proceeds”

   4.10(d)

“Guarantee Date”

   4.16

“Increased Amount”

   4.12

“Incremental Funds”

   4.07(a)

“Initial Default”

   6.02

“incur”

   4.09(a)

“Instructing Officers”

   7.02(m)

“Instructions”

   7.02(m)

“Junior Lien Intercreditor Agreement”

   12.02(d)

 

49


Term

   Defined in
Section

“Legal Defeasance”

   8.02

“Noteholder Direction”

   6.02

“Notes Offer”

   4.10(b)(1)(A)

“Offer Amount”

   3.09(b)

“Offer Period”

   3.09(b)

“Paying Agent”

   2.03

“Permitted Debt”

   4.09(b)

“Position Representation”

   6.02

“Purchase Date”

   3.09(b)

“Registrar”

   2.03

“Restricted Payments”

   4.07

“Reversion Date”

   4.18(b)

“Subject Lien”

   4.12

“Suspended Covenants”

   4.18(b)

“Transaction Election”

   1.04

“Transaction Test Date”

   1.04

“Verification Covenant”

   6.02

Section 1.03 Rules of Construction.

(a) Unless the context otherwise requires:

(1) the table of contents and headings are for convenience only and shall not affect the interpretation of this Indenture;

(2) unless otherwise specified, references to articles, sections, clauses, appendices, exhibits, schedules or annexes are references to articles, sections, clauses, appendices, exhibits, schedules or annexes to this Indenture;

(3) references to any party to this Indenture or any other document or agreement shall include its successors and permitted transferees and assigns;

(4) an “authorization” includes an authorization, consent, approval, resolution, license, exemption, filing, registration and notarization;

(5) “law” shall be construed as any law (including common or customary law), statute, constitution, decree, judgment, treaty, regulation, directive, by-law, order, ordinance or any other legislative measure of any government, supranational, local government, statutory or regulatory body or court, in each case having the force of law;

 

50


(6) unless as otherwise provided, any reference to assignment of a person’s rights and/or obligations shall be construed to refer to assignment, transfer or novation of those rights and/or obligations;

(7) any reference to the actions or omissions of agents, representatives or authorized persons shall refer only to actions or omissions taken in connection with the agency, representation or authorization;

(8) the omission of the word “any” or the phrase “if any” with respect to anything shall not imply that the thing exists or is required, notwithstanding the inclusion of such word or phrase (for clarity) in other provisions;

(9) any reference to an action being taken “pursuant to” an agreement or document, or any specified provision thereof, shall be construed to mean “pursuant to and in compliance with” the requirements of such agreement, document or provision;

(10) in some instances, a word or reference that, pursuant to these rules of interpretation, is not necessary (for example, inclusion of both the singular and plural), may be included for emphasis or clarity, and any such usage shall not give rise to any negative implication in relation to any other usage, which other usage shall nonetheless be interpreted strictly in accordance with the rules of interpretation set forth herein;

(11) a term has the meaning assigned to it;

(12) an accounting term not otherwise defined has the meaning assigned to it in accordance with GAAP;

(13) “or” is not exclusive;

(14) “including” means “including without limitation” whether or not stated;

(15) words in the singular include the plural, and in the plural include the singular;

(16) “will” shall be interpreted to express a command and shall be construed to have the same meaning and effect as the word “shall”;

(17) provisions apply to successive events and transactions;

(18) references to sections of or rules under the Securities Act will be deemed to include substitute, replacement of successor sections or rules adopted by the Commission from time to time; and

(19) references to any document, agreement or instrument means such document, agreement or instrument as it may be amended, amended and restated or otherwise modified in accordance with its terms.

 

51


Section 1.04 Limited Condition Transactions. Notwithstanding anything in this Indenture to the contrary, when (i) calculating availability under any applicable basket or ratio in this Indenture in connection with the incurrence of Indebtedness, the creation of Liens, the making of any Asset Sale, the making of any acquisitions, the making of an Investment, the making of a Restricted Payment, the designation of a Subsidiary as restricted or unrestricted, the repayment of Indebtedness or for any other purpose, (ii) determining whether any Default or Event of Default has occurred, is continuing or would result from any action, or (iii) determining compliance with any representations and warranties and any other condition precedent to any action or transaction, in each case of clauses (i) through (iii) in connection with a Limited Condition Transaction, the date of determination of such basket or ratio, whether any Default or Event of Default has occurred, is continuing or would result therefrom, or the satisfaction of any other condition precedent shall, at the option of the Issuer (the Issuer’s election to exercise such option in connection with any Limited Condition Transaction, a “Transaction Election”), be deemed to be the date of declaration of such Restricted Payment or the date that the definitive agreement for such Restricted Payment, Investment, acquisition, Asset Sale or incurrence, repayment, repurchase or refinancing of Indebtedness, Disqualified Stock or Preferred Equity is entered into, the date a public announcement of an intention to make an offer in respect of the target of such acquisition or Investment or the date of such notice, which may be conditional, of such repayment, repurchase or refinancing of Indebtedness, Disqualified Stock or Preferred Equity or such Asset Sale is given to the holders of such Indebtedness, Disqualified Stock or Preferred Equity (any such date, the “Transaction Test Date”). If on a pro forma basis after giving effect to such Limited Condition Transaction and the other transactions to be entered into in connection therewith (including any acquisitions, Investments, the incurrence or issuance of Indebtedness, Disqualified Stock or Preferred Stock and the use of proceeds thereof, the incurrence of Liens, repayments, Restricted Payments and Asset Sales) and any related pro forma adjustments, with such baskets and ratios, absence of defaults, satisfaction of conditions precedent and other provisions calculated as if such Limited Condition Transaction or other transactions had occurred on the relevant Transaction Test Date in compliance with the applicable baskets and ratios or other provisions, such provisions shall be deemed to have been complied with. For the avoidance of doubt, (i) if any of such baskets, ratios, absence of defaults, satisfaction of conditions precedent or other provisions are exceeded or breached as a result of fluctuations in such ratio (including due to fluctuations in Distributable Cash), a change in facts and circumstances or other provisions at or prior to the consummation of the relevant Limited Condition Transaction, such ratios, absence of defaults, satisfaction of conditions precedent and other provisions will not be deemed to have been exceeded, breached, or otherwise failed to have been satisfied as a result of such fluctuations or changed circumstances solely for purposes of determining whether the Limited Condition Transaction and any related transactions is permitted hereunder and (ii) such baskets and ratios and compliance with such conditions shall not be tested at the time of consummation of such Limited Condition Transaction or related transactions. If the Issuer has made a Transaction Election for any Limited Condition Transaction, then in connection with any subsequent calculation of any ratio or basket availability with respect to any other Limited Condition Transaction or otherwise on or following the relevant Transaction Test Date and prior to the earlier of the date on which such Limited Condition Transaction is consummated or the date that the definitive agreement for such Limited Condition Transaction is terminated or expires without consummation of such Limited Condition Transaction, any such ratio or basket shall be calculated on a pro forma basis assuming such Limited Condition Transaction and other transactions in connection therewith (including any incurrence of

 

52


Indebtedness and the use of proceeds thereof) have been consummated. For purposes of any calculation of any ratio that includes Fixed Charges or otherwise includes interest expense of any Indebtedness to be incurred, such Fixed Charges or interest expense may be calculated using an assumed interest rate for the Indebtedness to be incurred in connection with such Limited Condition Transaction based on the indicative interest margin contained in any financing commitment documentation with respect to such Indebtedness or, if no such indicative interest margin exists, as reasonably determined by the Issuer in good faith.

Section 1.05 Certain Compliance Calculations.

(a) Notwithstanding anything to the contrary herein, in the event an item of Indebtedness, Disqualified Stock or Preferred Equity (or any portion thereof) is incurred or issued, any Lien is incurred or other transaction is undertaken based on a ratio basket based on the Holdco Debt Ratio, such ratio(s) shall be calculated with respect to such incurrence, issuance or other transaction without giving effect to (a) amounts being utilized under any other basket (other than a ratio basket based on the Holdco Debt Ratio) on the same date, or (b) the incurrence of any Indebtedness under any revolving facility or letter of credit facility immediately prior to or in connection therewith. Each item of Indebtedness, Disqualified Stock or Preferred Equity that is incurred or issued, each Lien incurred and each other transaction undertaken will be deemed to have been incurred, issued or taken first, to the extent available, pursuant to the Holdco Debt Ratio test.

(b) For purposes of any calculation under this Indenture, the Issuer may elect, at any time (which election may not be changed with respect to such revolving Indebtedness), to either

(x) give pro forma effect to the incurrence of the entire committed amount of such revolving Indebtedness, in which case such committed amount may thereafter be borrowed or reborrowed, in whole or in part, from time to time, without further compliance with any provision under this Indenture, or (y) give pro forma effect to the incurrence of the actual amount drawn under such revolving Indebtedness, in which case, the ability to incur the amounts committed to under such revolving Indebtedness will be subject to the provisions of this Indenture.

Section 1.06 Acts of Holders.

(a) Any request, demand, authorization, direction, notice, consent, waiver or other action provided by this Indenture to be given or taken by Holders may be embodied in and evidenced by one or more instruments of substantially similar tenor signed by such Holders in person or by an agent duly appointed in writing. Except as herein otherwise expressly provided, such action shall become effective when such instrument or instruments are delivered to the Trustee and, where it is hereby expressly required, to the Issuer. Proof of execution of any such instrument or of a writing appointing any such agent, or the holding by any Person of a Note, shall be sufficient for any purpose of this Indenture and (subject to Section 7.01 hereof) conclusive in favor of the Trustee and the Issuer, if made in the manner provided in this Section 1.06.

(b) The fact and date of the execution by any Person of any such instrument or writing may be proved by the affidavit of a witness of such execution or by the certificate of any notary public or other officer authorized by law to take acknowledgments of deeds, certifying that the individual signing such instrument or writing acknowledged to him the execution thereof. Where

 

53


such execution is by or on behalf of any legal entity other than an individual, such certificate or affidavit shall also constitute proof of the authority of the Person executing the same. The fact and date of the execution of any such instrument or writing, or the authority of the Person executing the same, may also be proved in any other manner that the Trustee deems sufficient.

(c) Any request, demand, authorization, direction, notice, consent, waiver or other action by the Holder of any Note shall bind every future Holder of the same Note and the Holder of every Note issued upon the registration of transfer thereof or in exchange therefor or in lieu thereof, in respect of any action taken, suffered or omitted by the Trustee or the Issuer in reliance thereon, whether or not notation of such action is made upon such Note.

(d) The Issuer may set a record date for purposes of determining the identity of Holders entitled to give any request, demand, authorization, direction, notice, consent, waiver or take any other act, or to vote or consent to any action by vote or consent authorized or permitted to be given or taken by Holders. Unless otherwise specified, if not set by the Issuer prior to the first solicitation of a Holder made by any Person in respect of any such action, or in the case of any such vote, prior to such vote, any such record date shall be the later of 10 days prior to the first solicitation of such consent or the date of the most recent list of Holders furnished to the Trustee prior to such solicitation.

(e) Without limiting the foregoing, a Holder entitled to take any action hereunder with regard to any particular Note may do so with regard to all or any part of the principal amount of such Note or by one or more duly appointed agents, each of which may do so pursuant to such appointment with regard to all or any part of such principal amount. Any notice given or action taken by a Holder or its agents with regard to different parts of such principal amount pursuant to this Section 1.06(e) shall have the same effect as if given or taken by separate Holders of each such different part.

(f) Without limiting the generality of the foregoing, a Holder, including DTC and the Depositary, that is a Holder of a Global Note may make, give or take, by a proxy or proxies duly appointed in writing, any request, demand, authorization, direction, notice, consent, waiver or other action provided in this Indenture to be made, given or taken by Holders, and any Person that is a Holder of a Global Note, including DTC and the Depositary, may provide its proxy or proxies to the beneficial owners of interests in any such Global Note through such Depositary’s standing instructions and customary practices.

(g) The Issuer may fix a record date for the purpose of determining the Persons who are beneficial owners of interests in any Global Note held by DTC entitled under the procedures of such Depositary to make, give or take, by a proxy or proxies duly appointed in writing, any request, demand, authorization, direction, notice, consent, waiver or other action provided in this Indenture to be made, given or taken by Holders. If such a record date is fixed, the Holders on such record date or their duly appointed proxy or proxies, and only such Persons, shall be entitled to make, give or take such request, demand, authorization, direction, notice, consent, waiver or other action, whether or not such Holders remain Holders after such record date. No such request, demand, authorization, direction, notice, consent, waiver or other action shall be valid or effective if made, given or taken more than 120 days after such record date.

 

54


Section 1.07 Timing of Payment. Notwithstanding anything herein to the contrary, if the date on which any payment is to be made pursuant to this Indenture or the Notes is not a Business Day, the payment otherwise payable on such date shall be payable on the next succeeding Business Day with the same force and effect as if made on such scheduled date and (provided such payment is made on such succeeding Business Day) no interest shall accrue on the amount of such payment from and after such scheduled date to the time of such payment on such next succeeding Business Day and the amount of any such payment that is an interest payment will reflect accrual only through the original payment date and not through the next succeeding Business Day.

Section 1.08 Role of the Collateral Agent. The parties hereto agree that, in acting hereunder, the Collateral Agent shall be entitled to all of its rights, powers, protections and immunities set forth in the Collateral Agency Agreement (and that, in the case of any conflict between the provisions of this Indenture and the provisions of the Collateral Agency Agreement in respect of such rights, powers, protections and immunities only, the Collateral Agency Agreement shall prevail).

ARTICLE 2

THE NOTES

Section 2.01 Form and Dating.

(a) General. The Notes shall be in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The terms and provisions contained in the Notes will constitute, and are hereby expressly made, a part of this Indenture and the Issuer, the Guarantors and the Trustee, by their execution and delivery of this Indenture, expressly agree to such terms and provisions and to be bound thereby. However, to the extent any provision of any Note conflicts with the express provisions of this Indenture, the provisions of this Indenture shall govern and be controlling.

(b) Global Notes. Except as otherwise provided in this Section 2.01, Notes issued in global form (and the Trustee’s certificate of authentication of such Notes) will be substantially in the form of Exhibit A-1 or A-2 (including the Global Note Legend thereon and the “Schedule of Exchanges of Interests in the Global Note” attached thereto). Each such Note will be dated the date of its authentication. Except as otherwise provided in this Section 2.01, Notes issued in definitive form will be substantially in the form of Exhibit A-1 or A-2 (but without the Global Note Legend thereon and without the “Schedule of Exchanges of Interests in the Global Note” attached thereto). Each Global Note will represent such of the outstanding Notes as will be specified therein and each shall provide that it represents the aggregate principal amount of outstanding Notes from time to time endorsed thereon and that the aggregate principal amount of outstanding Notes represented thereby may from time to time be reduced or increased, as appropriate, to reflect exchanges and redemptions. Any endorsement of a Global Note to reflect the amount of any increase or decrease in the aggregate principal amount of outstanding Notes represented thereby will be made by the Trustee or the Custodian, at the direction of the Trustee, in accordance with instructions given by the Holder thereof as required by Section 2.06.

 

55


(c) Temporary Global Notes. Notes offered and sold in reliance on Regulation S shall be issued initially in the form of the Regulation S Temporary Global Notes duly executed by the Issuer and authenticated by the Trustee as hereinafter provided.

Following the termination of the applicable Restricted Period, the Regulation S Temporary Global Note Legend shall be deemed removed from the Regulation S Temporary Global Note for the Notes, following which temporary beneficial interests in the Regulation S Temporary Global Note shall automatically become beneficial interests in the Regulation S Permanent Global Note of the Notes pursuant to the Applicable Procedures.

The aggregate principal amount of a Regulation S Temporary Global Note for the Notes and a Regulation S Permanent Global Note of the Notes may from time to time be increased or decreased by adjustments made on the records of the Trustee and/or the Paying Agent and the Depositary or their respective nominees, as the case may be, in connection with transfers of interest as hereinafter provided.

(d) Euroclear and Clearstream Procedures Applicable. The provisions of the “Operating Procedures of the Euroclear System” and “Terms and Conditions Governing Use of Euroclear” and the “General Terms and Conditions of Clearstream Banking” and “Customer Handbook” of Clearstream will be applicable to transfers of beneficial interests in the Regulation S Temporary Global Note and the Regulation S Permanent Global Note that are held by Participants through Euroclear or Clearstream.

(e) Additional Notes. Subject to compliance with the provisions of this Indenture, the Issuer may, without notice to or the consent of the Holders from time to time after the Issue Date issue Additional Notes, ranking pari passu with the Initial Notes, and such Additional Notes shall be consolidated with and form a single class with the Initial Notes (except as otherwise provided for herein) and shall have the same terms as the Initial Notes (except for any differences in the issue price, the issue date and the interest accrued, if any); provided, however, that a separate CUSIP or ISIN will be issued for the Additional Notes, unless the Additional Notes are fungible with the Initial for U.S. federal income tax purposes. Any Additional Notes shall be issued with the benefit of an indenture supplemental to this Indenture.

Section 2.02 Execution and Authentication.

At least one Officer must sign the Notes for the Issuer by manual or electronic signature.

If an Officer whose signature is on a Note no longer holds that office at the time a Note is authenticated, the Note will nevertheless be valid.

A Note will not be valid until authenticated by the manual or electronic signature of the Trustee. The signature will be conclusive evidence that the Note has been authenticated under this Indenture.

At any time and from time to time after the execution and delivery of this Indenture, the Issuer may deliver Notes executed by the Company to the Trustee for authentication, together with a written order of the Issuer signed by at least one Officer for the authentication and delivery of such Notes (an “Authentication Order”), and the Trustee in accordance with such Authentication

 

56


Order shall authenticate and deliver such Notes, without any further action by the Issuer hereunder; provided that the Trustee shall be entitled to receive an Officer’s Certificate and an Opinion of Counsel with respect to the issuance, authentication and delivery of any Additional Notes. The aggregate principal amount of Notes outstanding at any time may not exceed the aggregate principal amount of Notes authorized for issuance by the Issuer pursuant to one or more Authentication Orders, except as provided in Section 2.07.

The Trustee may appoint an authenticating agent acceptable to the Issuer to authenticate Notes. An authenticating agent may authenticate Notes whenever the Trustee may do so. Each reference in this Indenture to authentication by the Trustee includes authentication by such agent. An authenticating agent has the same rights as an Agent to deal with Holders or an Affiliate of the Issuer.

For the avoidance of any doubt, any Additional Notes that are issued in connection with a transaction in which an Officer’s Certificate and Opinion of Counsel was delivered shall be valid for all purposes and constitute Additional Notes hereunder, even if subsequently it is determined that such issuance was not in compliance with the covenants of this Indenture.

Section 2.03 Registrar and Paying Agent.

The Issuer will maintain an office or agency where Notes may be presented for registration of transfer or for exchange (“Registrar”) and an office or agency where Notes may be presented for payment (“Paying Agent”). The Registrar will keep a register of the Notes and of their transfer and exchange. The Issuer may appoint one or more co-registrars and one or more additional paying agents. The term “Registrar” includes any co-registrar and the term “Paying Agent” includes any additional paying agent. The Issuer may change any Paying Agent or Registrar without notice to any Holder. The Issuer will notify the Trustee in writing of the name and address of any Agent not a party to this Indenture. If the Issuer fails to appoint or maintain another entity as Registrar or Paying Agent, the Trustee shall act as such. The Issuer or any of its Subsidiaries may act as Paying Agent or Registrar.

The Issuer initially appoints The Depository Trust Company (“DTC”) to act as Depositary with respect to the Global Notes.

The Issuer initially appoints the Trustee to act as the Registrar and Paying Agent and to act as Custodian with respect to the Global Notes.

Section 2.04 Paying Agent to Hold Money in Trust.

The Issuer will require each Paying Agent other than the Trustee to agree in writing that the Paying Agent will hold in trust for the benefit of Holders or the Trustee all money held by the Paying Agent for the payment of principal, premium, or interest on the Notes, and will notify the Trustee of any default by the Issuer in making any such payment. While any such default continues, the Trustee may require a Paying Agent to pay all money held by it to the Trustee. The Issuer at any time may require a Paying Agent to pay all money held by it to the Trustee. Upon payment over to the Trustee, the Paying Agent (if other than the Issuer or a Subsidiary) will have no further liability for the money. If the Issuer or a Subsidiary acts as Paying Agent, it will segregate and hold in a separate trust fund for the benefit of the Holders all money held by it as Paying Agent. Upon any bankruptcy or reorganization proceedings relating to the Issuer, the Trustee will serve as Paying Agent for the Notes.

 

57


Section 2.05 Holder Lists.

The Trustee will preserve in as current a form as is reasonably practicable the most recent list available to it of the names and addresses of all Holders. If the Trustee is not the Registrar, the Issuer on its own behalf and on behalf of the Guarantors will furnish to the Trustee at least seven Business Days before each Interest Payment Date and at such other times as the Trustee may request in writing, a list in such form and as of such date as the Trustee may reasonably require of the names and addresses of the Holders.

Section 2.06 Transfer and Exchange.

(a) Transfer and Exchange of Global Notes. A Global Note may not be transferred except as a whole by the Depositary to a nominee of the Depositary, by a nominee of the Depositary to the Depositary or to another nominee of the Depositary, or by the Depositary or any such nominee to a successor Depositary or a nominee of such successor Depositary. All Global Notes will be exchanged by the Issuer for Definitive Notes if:

(1) the Depositary notifies the Issuer that it is unwilling or unable to continue to act as Depositary for the Global Notes or that it has ceased to be a clearing agency registered under the Exchange Act and, in either case, a successor Depositary is not appointed by the Issuer within 120 days after the date of such notice from the Depositary;

(2) the Issuer, at its option, notifies the Trustee in writing that it elects to cause this issuance of Definitive Notes; provided that in no event shall the Regulation S Temporary Global Note be exchanged by the Issuer for Definitive Notes prior to (A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903(b)(3)(ii)(B) under the Securities Act; or

(3) there has occurred and is continuing an Event of Default with respect to the Notes.

Upon the occurrence of any of the preceding events, Definitive Notes shall be issued and delivered in such names as the Depositary shall instruct the Trustee, in accordance with the Depositary’s customary procedures. Global Notes also may be exchanged or replaced, in whole or in part, as provided in Section 2.07 and Section 2.10. Every Note authenticated and delivered in exchange for, or in lieu of, a Global Note or any portion thereof, pursuant to this Section 2.06 or Section 2.07 or Section 2.10, shall be authenticated and delivered in the form of, and shall be, a Global Note. A Global Note may not be exchanged for another Note other than as provided in this Section 2.06(a), however, beneficial interests in a Global Note may be transferred and exchanged as provided in Section 2.06(b) or (c).

 

58


(b) Transfer and Exchange of Beneficial Interests in the Global Notes. The transfer and exchange of beneficial interests in the Global Notes will be effected through the Depositary, in accordance with the provisions of this Indenture and the Applicable Procedures. Beneficial interests in the Restricted Global Notes will be subject to restrictions on transfer comparable to those set forth herein to the extent required by the Securities Act. Transfers of beneficial interests in the Global Notes also will require compliance with either subparagraph (1) or (2) below, as applicable, as well as one or more of the other following subparagraphs, as applicable:

(1) Transfer of Beneficial Interests in the Same Global Note. Beneficial interests in any Restricted Global Note may be transferred to Persons who take delivery thereof in the form of a beneficial interest in the same Restricted Global Note in accordance with the transfer restrictions set forth in the Private Placement Legend; provided, however, that prior to the expiration of the Restricted Period, transfers of beneficial interests in the Regulation S Temporary Global Note may not be made to a U.S. Person or for the account or benefit of a U.S. Person (other than the Initial Purchasers). Beneficial interests in any Unrestricted Global Note may be transferred to Persons who take delivery thereof in the form of a beneficial interest in an Unrestricted Global Note. No written orders or instructions shall be required to be delivered to the Registrar to effect the transfers described in this Section 2.06(b)(1).

(2) All Other Transfers and Exchanges of Beneficial Interests in Global Notes. In connection with all transfers and exchanges of beneficial interests that are not subject to Section 2.06(b)(1), the transferor of such beneficial interest must deliver to the Registrar either:

(A) both:

(i) an order from a Participant or an Indirect Participant given to the Depositary in accordance with the Applicable Procedures directing the Depositary to credit or cause to be credited a beneficial interest in another Global Note in an amount equal to the beneficial interest to be transferred or exchanged; and

(ii) instructions given in accordance with the Applicable Procedures containing information regarding the Participant account to be credited with such increase; or

(B) both:

(i) an order from a Participant or an Indirect Participant given to the Depositary in accordance with the Applicable Procedures directing the Depositary to cause to be issued a Definitive Note in an amount equal to the beneficial interest to be transferred or exchanged; and

(ii) instructions given by the Depositary to the Registrar containing information regarding the Person in whose name such Definitive Note shall be registered to effect the transfer or exchange referred to in (1) above;

provided that in no event shall Definitive Notes be issued upon the transfer or exchange of beneficial interests in the Regulation S Temporary Global Note prior to (A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903 under the Securities Act.

 

59


Upon satisfaction of all of the requirements for transfer or exchange of beneficial interests in Global Notes contained in this Indenture and the Notes or otherwise applicable under the Securities Act, the Trustee shall adjust the principal amount of the relevant Global Note(s) pursuant to Section 2.06(h).

(3) Transfer of Beneficial Interests to Another Restricted Global Note. A beneficial interest in any Restricted Global Note may be transferred to a Person who takes delivery thereof in the form of a beneficial interest in another Restricted Global Note if the transfer complies with the requirements of Section 2.06(b)(2) and the Registrar receives the following:

(A) if the transferee will take delivery in the form of a beneficial interest in the Rule 144A Global Note, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (1) thereof;

(B) if the transferee will take delivery in the form of a beneficial interest in the Regulation S Temporary Global Note or the Regulation S Permanent Global Note, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (2) thereof; and

(C) if the transferee will take delivery in the form of a beneficial interest in the IAI Global Note, then the transferor must deliver a certificate in the form of Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable.

(4) Transfer and Exchange of Beneficial Interests in a Restricted Global Note for Beneficial Interests in an Unrestricted Global Note. A beneficial interest in any Restricted Global Note may be exchanged by any Holder thereof for a beneficial interest in an Unrestricted Global Note or transferred to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note if the exchange or transfer complies with the requirements of Section 2.06(b)(2) and the Registrar receives the following:

(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a beneficial interest in an Unrestricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(a) thereof; or

(B) if the Holder of such beneficial interest in a Restricted Global Note proposes to transfer such beneficial interest to a Person who shall take delivery thereof in the form of a beneficial interest in an Unrestricted Global Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof; and, in each such case set forth in this clause (4), if the Registrar so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Issuer to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

 

60


If any such transfer is effected pursuant to this clause (4) at a time when an Unrestricted Global Note has not yet been issued, the Issuer shall issue and, upon receipt of an Authentication Order in accordance with Section 2.02, the Trustee shall authenticate one or more Unrestricted Global Notes in an aggregate principal amount equal to the aggregate principal amount of beneficial interests transferred pursuant to this clause (4).

Beneficial interests in an Unrestricted Global Note cannot be exchanged for, or transferred to Persons who take delivery thereof in the form of, a beneficial interest in a Restricted Global Note.

(c) Transfer or Exchange of Beneficial Interests for Definitive Notes.

(1) Beneficial Interests in Restricted Global Notes to Restricted Definitive Notes. If any Holder of a beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a Restricted Definitive Note or to transfer such beneficial interest to a Person who takes delivery thereof in the form of a Restricted Definitive Note, then, upon receipt by the Registrar of the following documentation:

(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a Restricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (2)(a) thereof;

(B) if such beneficial interest is being transferred to a QIB in accordance with Rule 144A, a certificate to the effect set forth in Exhibit B, including the certifications in item (1) thereof;

(C) if such beneficial interest is being transferred to a Non-U.S. Person in an offshore transaction in accordance with Rule 903 or Rule 904, a certificate to the effect set forth in Exhibit B, including the certifications in item (2) thereof;

(D) if such beneficial interest is being transferred pursuant to an exemption from the registration requirements of the Securities Act in accordance with Rule 144, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(a) thereof;

(E) if such beneficial interest is being transferred to an Institutional Accredited Investor in reliance on an exemption from the registration requirements of the Securities Act other than those listed in subparagraphs (B) through (D) above, a certificate to the effect set forth in Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable;

 

61


(F) if such beneficial interest is being transferred to the Issuer or any of its Subsidiaries, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(b) thereof; or

(G) if such beneficial interest is being transferred pursuant to an effective registration statement under the Securities Act, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(c) thereof,

the Trustee shall cause the aggregate principal amount of the applicable Global Note to be reduced accordingly pursuant to Section 2.06(h), and the Issuer shall execute and the Trustee shall authenticate and deliver to the Person designated in the instructions a Definitive Note in the appropriate principal amount. Any Definitive Note issued in exchange for a beneficial interest in a Restricted Global Note pursuant to this Section 2.06(c) shall be registered in such name or names and in such authorized denomination or denominations as the Holder of such beneficial interest shall instruct the Registrar through instructions from the Depositary and the Participant or Indirect Participant. The Trustee shall deliver such Definitive Notes to Holders of such Notes. Any Definitive Note issued in exchange for a beneficial interest in a Restricted Global Note pursuant to this Section 2.06(c)(1) shall bear the Private Placement Legend and shall be subject to all restrictions on transfer contained therein.

(2) Beneficial Interests in Regulation S Temporary Global Note to Definitive Notes. Notwithstanding Sections 2.06(c)(1)(A) and (C), a beneficial interest in the Regulation S Temporary Global Note may not be exchanged for a Definitive Note or transferred to a Person who takes delivery thereof in the form of a Definitive Note prior to (A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903(b)(3)(ii)(B) under the Securities Act, except in the case of a transfer pursuant to an exemption from the registration requirements of the Securities Act other than Rule 903 or Rule 904.

(3) Beneficial Interests in Restricted Global Notes to Unrestricted Definitive Notes. A Holder of a beneficial interest in a Restricted Global Note may exchange such beneficial interest for an Unrestricted Definitive Note or may transfer such beneficial interest to a Person who takes delivery thereof in the form of an Unrestricted Definitive Note only if the Registrar receives the following:

(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(b) thereof; or

(B) if the Holder of such beneficial interest in a Restricted Global Note proposes to transfer such beneficial interest to a Person who shall take delivery thereof in the form of an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

 

62


and, in each such case set forth in this clause (3), if the Registrar so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Issuer to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

(4) Beneficial Interests in Unrestricted Global Notes to Unrestricted Definitive Notes. If any Holder of a beneficial interest in an Unrestricted Global Note proposes to exchange such beneficial interest for a Definitive Note or to transfer such beneficial interest to a Person who takes delivery thereof in the form of a Definitive Note, then, upon satisfaction of the conditions set forth in Section 2.06(b)(2), the Trustee will cause the aggregate principal amount of the applicable Global Note to be reduced accordingly pursuant to Section 2.06(h), and the Issuer will execute and the Trustee will authenticate and deliver to the Person designated in the instructions a Definitive Note in the appropriate principal amount. Any Definitive Note issued in exchange for a beneficial interest pursuant to this Section 2.06(c)(4) will be registered in such name or names and in such authorized denomination or denominations as the Holder of such beneficial interest requests through instructions to the Registrar from or through the Depositary and the Participant or Indirect Participant. The Trustee will deliver such Definitive Notes to Holders of such Notes. Any Definitive Note issued in exchange for a beneficial interest pursuant to this Section 2.06(c)(4) will not bear the Private Placement Legend.

(d) Transfer and Exchange of Definitive Notes for Beneficial Interests.

(1) Restricted Definitive Notes to Beneficial Interests in Restricted Global Notes. If any Holder of a Restricted Definitive Note proposes to exchange such Note for a beneficial interest in a Restricted Global Note or to transfer such Restricted Definitive Notes to a Person who takes delivery thereof in the form of a beneficial interest in a Restricted Global Note, then, upon receipt by the Registrar of the following documentation:

(A) if the Holder of such Restricted Definitive Note proposes to exchange such Note for a beneficial interest in a Restricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (2)(b) thereof;

(B) if such Restricted Definitive Note is being transferred to a QIB in accordance with Rule 144A, a certificate to the effect set forth in Exhibit B, including the certifications in item (1) thereof;

(C) if such Restricted Definitive Note is being transferred to a Non-U.S. Person in an offshore transaction in accordance with Rule 903 or Rule 904, a certificate to the effect set forth in Exhibit B, including the certifications in item (2) thereof;

(D) if such Restricted Definitive Note is being transferred pursuant to an exemption from the registration requirements of the Securities Act in accordance with Rule 144, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(a) thereof;

 

63


(E) if such Restricted Definitive Note is being transferred to an Institutional Accredited Investor in reliance on an exemption from the registration requirements of the Securities Act other than those listed in subparagraphs (B) through (D) above, a certificate to the effect set forth in Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable;

(F) if such Restricted Definitive Note is being transferred to the Issuer or any of its Subsidiaries, a certificate to the effect set forth in Exhibit B hereto, including the certifications in item (3)(b) thereof; or

(G) if such Restricted Definitive Note is being transferred pursuant to an effective registration statement under the Securities Act, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(c) thereof,

the Trustee will cancel the Restricted Definitive Note, increase or cause to be increased the aggregate principal amount of, in the case of clause (A) above, the appropriate Restricted Global Note, in the case of clause (B) above, the Rule 144A Global Note, in the case of clause (C) above, the Regulation S Global Note, in the case of clause (E) above, the IAI Global Note and in all other cases, the appropriate Unrestricted Global Note.

(2) Restricted Definitive Notes to Beneficial Interests in Unrestricted Global Notes. A Holder of a Restricted Definitive Note may exchange such Note for a beneficial interest in an Unrestricted Global Note or transfer such Restricted Definitive Note to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note only if the Registrar receives the following:

(A) if the Holder of such Definitive Notes proposes to exchange such Notes for a beneficial interest in the Unrestricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(c) thereof; or

(B) if the Holder of such Definitive Notes proposes to transfer such Notes to a Person who shall take delivery thereof in the form of a beneficial interest in the Unrestricted Global Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

and, in each such case set forth in this clause (2), if the Registrar so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Issuer to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

Upon satisfaction of the conditions of any of the subparagraphs in this Section 2.06(d)(2), the Trustee will cancel the Definitive Notes and increase or cause to be increased the aggregate principal amount of the Unrestricted Global Note.

 

64


(3) Unrestricted Definitive Notes to Beneficial Interests in Unrestricted Global Notes. A Holder of an Unrestricted Definitive Note may exchange such Note for a beneficial interest in an Unrestricted Global Note or transfer such Definitive Notes to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note at any time. Upon receipt of a request for such an exchange or transfer, the Trustee will cancel the applicable Unrestricted Definitive Note and increase or cause to be increased the aggregate principal amount of one of the Unrestricted Global Notes.

If any such exchange or transfer from a Definitive Note to a beneficial interest is effected pursuant to subparagraphs (2) or (3) above at a time when an Unrestricted Global Note has not yet been issued, the Issuer will issue and, upon receipt of an Authentication Order in accordance with Section 2.02, the Trustee will authenticate one or more Unrestricted Global Notes in an aggregate principal amount equal to the principal amount of Definitive Notes so transferred.

(e) Transfer and Exchange of Definitive Notes for Definitive Notes. Upon request by a Holder of Definitive Notes and such Holder’s compliance with the provisions of this Section 2.06(e), the Registrar will register the transfer or exchange of Definitive Notes. Prior to such registration of transfer or exchange, the requesting Holder must present or surrender to the Registrar the Definitive Notes duly endorsed or accompanied by a written instruction of transfer in form satisfactory to the Registrar duly executed by such Holder or by its attorney, duly authorized in writing. In addition, the requesting Holder must provide any additional certifications, documents and information, as applicable, required pursuant to the following provisions of this Section 2.06(e).

(1) Restricted Definitive Notes to Restricted Definitive Notes. Any Restricted Definitive Note may be transferred to and registered in the name of Persons who take delivery thereof in the form of a Restricted Definitive Note if the Registrar receives the following:

(A) if the transfer will be made pursuant to Rule 144A, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (1) thereof;

(B) if the transfer will be made pursuant to Rule 903 or Rule 904, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (2) thereof; and

(C) if the transfer will be made pursuant to any other exemption from the registration requirements of the Securities Act, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable.

 

65


(2) Restricted Definitive Notes to Unrestricted Definitive Notes. Any Restricted Definitive Note may be exchanged by the Holder thereof for an Unrestricted Definitive Note or transferred to a Person or Persons who take delivery thereof in the form of an Unrestricted Definitive Note if the Registrar receives the following:

(A) if the Holder of such Restricted Definitive Notes proposes to exchange such Notes for an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(d) thereof; or

(B) if the Holder of such Restricted Definitive Notes proposes to transfer such Notes to a Person who shall take delivery thereof in the form of an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

and, in each such case set forth in this clause (2), if the Registrar so requests, an Opinion of Counsel in form reasonably acceptable to the Registrar to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

(3) Unrestricted Definitive Notes to Unrestricted Definitive Notes. A Holder of Unrestricted Definitive Notes may transfer such Notes to a Person who takes delivery thereof in the form of an Unrestricted Definitive Note. Upon receipt of a request to register such a transfer, the Registrar shall register the Unrestricted Definitive Notes pursuant to the instructions from the Holder thereof.

(f) [Reserved].

(g) Legends. The following legends will appear on the face of all Global Notes and Definitive Notes issued under this Indenture unless specifically stated otherwise in the applicable provisions of this Indenture or any supplemental indenture governing Additional Notes.

(1) Private Placement Legend.

(A) Except as permitted by subparagraph (B) below, each Global Note and each Definitive Note (and all Notes issued in exchange therefor or substitution thereof) shall bear the legend in substantially the following form:

“THIS SECURITY HAS NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), OR THE SECURITIES LAWS OF ANY STATE OR OTHER JURISDICTION. NEITHER THIS SECURITY NOR ANY INTEREST OR PARTICIPATION HEREIN MAY BE REOFFERED, SOLD, ASSIGNED, TRANSFERRED, PLEDGED, ENCUMBERED OR OTHERWISE DISPOSED OF IN THE ABSENCE OF SUCH REGISTRATION OR UNLESS SUCH TRANSACTION IS EXEMPT FROM, OR NOT SUBJECT TO, SUCH REGISTRATION. THE HOLDER OF THIS SECURITY, BY ITS ACCEPTANCE HEREOF, AGREES ON ITS OWN BEHALF AND ON BEHALF OF ANY INVESTOR ACCOUNT FOR WHICH IT HAS PURCHASED SECURITIES, TO OFFER, SELL OR OTHERWISE TRANSFER SUCH SECURITY, ONLY (A) TO THE ISSUER, (B) PURSUANT TO A REGISTRATION STATEMENT THAT HAS BECOME OR BEEN DECLARED EFFECTIVE UNDER THE SECURITIES ACT, (C) FOR SO LONG

 

66


AS THE SECURITIES ARE ELIGIBLE FOR RESALE PURSUANT TO RULE 144A UNDER THE SECURITIES ACT, TO A PERSON IT REASONABLY BELIEVES IS A “QUALIFIED INSTITUTIONAL BUYER” AS DEFINED IN RULE 144A UNDER THE SECURITIES ACT THAT PURCHASES FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF A QUALIFIED INSTITUTIONAL BUYER TO WHOM NOTICE IS GIVEN THAT THE TRANSFER IS BEING MADE IN RELIANCE ON RULE 144A, (D) PURSUANT TO OFFERS AND SALES THAT OCCUR OUTSIDE THE UNITED STATES IN ACCORDANCE WITH REGULATION S UNDER THE SECURITIES ACT, (E) TO AN INSTITUTIONAL “ACCREDITED INVESTOR” WITHIN THE MEANING OF RULE 501(a)(1), (2), (3) OR (7) UNDER THE SECURITIES ACT THAT IS AN INSTITUTIONAL ACCREDITED INVESTOR ACQUIRING THE SECURITY FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF SUCH AN INSTITUTIONAL ACCREDITED INVESTOR, IN EACH CASE IN A MINIMUM PRINCIPAL AMOUNT OF THE SECURITIES OF $250,000, FOR INVESTMENT PURPOSES AND NOT WITH A VIEW TO OR FOR OFFER OR SALE IN CONNECTION WITH ANY DISTRIBUTION IN VIOLATION OF THE SECURITIES ACT, (F) PURSUANT TO THE EXEMPTION FROM REGISTRATION PROVIDED BY RULE 144 UNDER THE SECURITIES ACT (IF AVAILABLE) OR (G) PURSUANT TO ANOTHER AVAILABLE EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT, SUBJECT TO THE ISSUER’S AND THE TRUSTEE’S RIGHT PRIOR TO ANY SUCH OFFER, SALE OR TRANSFER PURSUANT TO CLAUSES (D), (E), (F) OR (G) TO REQUIRE THE DELIVERY OF AN OPINION OF COUNSEL, CERTIFICATION AND/OR OTHER INFORMATION SATISFACTORY TO EACH OF THEM. THIS LEGEND WILL BE REMOVED UPON THE REQUEST OF THE HOLDER AFTER THE RESALE RESTRICTION TERMINATION DATE.”

(B) Notwithstanding the foregoing, any Global Note or Definitive Note issued pursuant to subparagraphs (b)(4), (c)(3), (c)(4), (d)(2), (d)(3), (e)(2) or (e)(3) of this Section 2.06 (and all Notes issued in exchange therefor or substitution thereof) will not bear the Private Placement Legend.

(2) Global Note Legend. Each Global Note will bear a legend in substantially the following form:

“THIS GLOBAL NOTE IS HELD BY THE DEPOSITARY (AS DEFINED IN THE INDENTURE GOVERNING THIS NOTE) OR ITS NOMINEE IN CUSTODY FOR THE BENEFIT OF THE BENEFICIAL OWNERS HEREOF, AND IS NOT TRANSFERABLE TO ANY PERSON UNDER ANY CIRCUMSTANCES EXCEPT THAT (1) THE TRUSTEE MAY MAKE SUCH NOTATIONS HEREON AS MAY BE REQUIRED PURSUANT TO SECTION 2.06 OF THE INDENTURE, (2) THIS GLOBAL NOTE MAY BE EXCHANGED IN WHOLE BUT NOT IN PART PURSUANT TO SECTION 2.06(a) OF THE INDENTURE, (3) THIS GLOBAL NOTE MAY BE DELIVERED TO THE TRUSTEE FOR CANCELLATION PURSUANT TO SECTION 2.11 OF THE INDENTURE AND (4) THIS GLOBAL NOTE MAY BE TRANSFERRED TO A SUCCESSOR DEPOSITARY WITH THE PRIOR WRITTEN CONSENT OF THE ISSUER.

 

67


UNLESS AND UNTIL IT IS EXCHANGED IN WHOLE OR IN PART FOR NOTES IN DEFINITIVE FORM, THIS NOTE MAY NOT BE TRANSFERRED EXCEPT AS A WHOLE BY THE DEPOSITARY TO A NOMINEE OF THE DEPOSITARY OR BY A NOMINEE OF THE DEPOSITARY TO THE DEPOSITARY OR ANOTHER NOMINEE OF THE DEPOSITARY OR BY THE DEPOSITARY OR ANY SUCH NOMINEE TO A SUCCESSOR DEPOSITARY OR A NOMINEE OF SUCH SUCCESSOR DEPOSITARY. UNLESS THIS CERTIFICATE IS PRESENTED BY AN AUTHORIZED REPRESENTATIVE OF THE DEPOSITORY TRUST COMPANY (55 WATER STREET, NEW YORK, NEW YORK) (“DTC”), TO THE ISSUER OR ITS AGENT FOR REGISTRATION OF TRANSFER, EXCHANGE OR PAYMENT, AND ANY CERTIFICATE ISSUED IS REGISTERED IN THE NAME OF CEDE & CO. OR SUCH OTHER NAME AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC (AND ANY PAYMENT IS MADE TO CEDE & CO. OR SUCH OTHER ENTITY AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC), ANY TRANSFER, PLEDGE OR OTHER USE HEREOF FOR VALUE OR OTHERWISE BY OR TO ANY PERSON IS WRONGFUL INASMUCH AS THE REGISTERED OWNER HEREOF, CEDE & CO., HAS AN INTEREST HEREIN.”

(3) Regulation S Temporary Global Note Legend. The Regulation S Temporary Global Note will bear a legend in substantially the following form:

“THIS SECURITY HAS NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), OR THE SECURITIES LAWS OF ANY STATE OR OTHER JURISDICTION, AND MAY NOT BE OFFERED, SOLD OR DELIVERED IN THE UNITED STATES OR TO, OR FOR THE ACCOUNT OR BENEFIT OF, ANY US PERSON, UNLESS SUCH NOTES ARE REGISTERED UNDER THE SECURITIES ACT OR AN EXEMPTION FROM THE REGISTRATION REQUIREMENTS THEREOF IS AVAILABLE. THIS LEGEND WILL BE REMOVED AFTER THE EXPIRATION OF FORTY DAYS FROM THE LATER OF (i) THE DATE ON WHICH THESE NOTES WAS FIRST OFFERED AND (ii) THE DATE OF ISSUE OF THESE NOTES.”

(h) Cancellation and/or Adjustment of Global Notes. At such time as all beneficial interests in a particular Global Note have been exchanged for Definitive Notes or a particular Global Note has been redeemed, repurchased or canceled in whole and not in part, each such Global Note will be returned to or retained and canceled by the Trustee in accordance with Section 2.11. At any time prior to such cancellation, if any beneficial interest in a Global Note is exchanged for or transferred to a Person who will take delivery thereof in the form of a beneficial interest in another Global Note or for Definitive Notes, the principal amount of Notes represented by such Global Note will be reduced accordingly and an endorsement will be made on such Global

 

68


Note by the Trustee or by the Depositary at the direction of the Trustee to reflect such reduction; and if the beneficial interest is being exchanged for or transferred to a Person who will take delivery thereof in the form of a beneficial interest in another Global Note, such other Global Note will be increased accordingly and an endorsement will be made on such Global Note by the Trustee or by the Depositary at the direction of the Trustee to reflect such increase.

(i) General Provisions Relating to Transfers and Exchanges.

(1) To permit registrations of transfers and exchanges, the Issuer will execute and the Trustee will authenticate Global Notes and Definitive Notes upon receipt of an Authentication Order in accordance with Section 2.02 or at the Registrar’s request.

(2) No service charge will be made to a Holder of a beneficial interest in a Global Note or to a Holder of a Definitive Note for any registration of transfer or exchange, but the Issuer may require payment of a sum sufficient to cover any transfer tax or similar governmental charge payable in connection therewith (other than any such transfer taxes or similar governmental charge payable upon exchange or transfer pursuant to Section 2.10, Section 3.06, Section 3.09, Section 4.12 and Section 4.17).

(3) The Registrar will not be required to register the transfer of or exchange of any Note selected for redemption in whole or in part, except the unredeemed portion of any Note being redeemed in part.

(4) All Global Notes and Definitive Notes issued upon any registration of transfer or exchange of Global Notes or Definitive Notes will be the valid obligations of the Issuer, evidencing the same debt, and entitled to the same benefits under this Indenture, as the Global Notes or Definitive Notes surrendered upon such registration of transfer or exchange.

(5) Neither the Registrar nor the Issuer will be required:

(A) to issue, to register the transfer of or to exchange any Notes during a period beginning at the opening of business 15 days before the day of any selection of Notes for redemption under Section 3.02 and ending at the close of business on the day of selection;

(B) to register the transfer of or to exchange any Note selected for redemption in whole or in part, except the unredeemed portion of any Note being redeemed in part; or

(C) to register the transfer of or to exchange a Note between a record date and the next succeeding Interest Payment Date.

(6) Prior to due presentment for the registration of a transfer of any Note, the Trustee, any Agent and the Issuer may deem and treat any Holder as the absolute owner of such Note for the purpose of receiving payment of principal of and interest on such Notes and for all other purposes, and none of the Trustee, any Agent or the Issuer shall be affected by notice to the contrary.

 

69


(7) The Trustee will authenticate Global Notes and Definitive Notes in accordance with the provisions of Section 2.02.

(8) All certifications, certificates and Opinions of Counsel required to be submitted to the Registrar pursuant to this Section 2.06 to effect a registration of transfer or exchange may be submitted by facsimile.

(9) None of the Trustee or any Agent shall have any responsibility or obligation to any beneficial owner in a Global Note, an agent member of the Depositary or other Person with respect to the accuracy of the records of the Depositary or its nominee or of any agent member of the Depositary, with respect to any ownership interest in the Notes or with respect to the delivery to any agent member of the Depositary, beneficial owner or other Person (other than the Depositary) of any notice (including any notice of redemption) or the payment of any amount, under or with respect to such Notes. All notices and communications to be given to the Holders and all payments to be made to Holders under the Notes and this Indenture shall be given or made only to or upon the order of the registered holders (which shall be the Depositary or its nominee in the case of the Global Note). The rights of beneficial owners in the Global Note shall be exercised only through the Depositary subject to the applicable procedures. The Trustee and each Agent shall be entitled to rely and shall be fully protected in relying upon information furnished by the Depositary with respect to its members, participants and any beneficial owners. The Trustee and each Agent shall be entitled to deal with the Depositary, and any nominee thereof, that is the registered holder of any Global Note for all purposes of this Indenture relating to such Global Note (including the payment of principal, premium, if any, and interest, and the giving of instructions or directions by or to the owner or holder of a beneficial ownership interest in such Global Note) as the sole holder of such Global Note and shall have no obligations to the beneficial owners thereof. None of the Trustee or any Agent shall have any responsibility or liability for any acts or omissions of the Depositary with respect to such Global Note, for the records of any such depositary, including records in respect of beneficial ownership interests in respect of any such Global Note, for any transactions between the Depositary and any agent member of the Depositary or between or among the Depositary, any such agent member of the Depositary and/or any holder or owner of a beneficial interest in such Global Note, or for any transfers of beneficial interests in any such Global Note.

(10) Notwithstanding the foregoing, with respect to any Global Note, nothing herein shall prevent the Issuer, the Trustee, any Agent, or any agent of the Issuer or the Trustee from giving effect to any written certification, proxy or other authorization furnished by any Depositary (or its nominee), as a Holder, with respect to such Global Note or shall impair, as between such Depositary and owners of beneficial interests in such Global Note, the operation of customary practices governing the exercise of the rights of such Depositary (or its nominee) as Holder of such Global Note.

None of the Trustee or any Agent shall have any obligation or duty to monitor, determine or inquire as to compliance with any restrictions on transfer imposed under this Indenture or under applicable law with respect to any transfer of any interest in any security (including any transfers between or among Depositary participants, members or beneficial owners in any Global Note) other than to require delivery of such certificates and other documentation or evidence as are expressly required by, and to do so if and when expressly required by, the terms of this Indenture, and to examine the same to determine substantial compliance as to form with the express requirements hereof.

 

70


Section 2.07 Replacement Notes.

If any mutilated Note is surrendered to the Trustee or the Issuer and the Trustee receives evidence to its satisfaction of the destruction, loss or theft of any Note, the Issuer will issue and the Trustee, upon receipt of an Authentication Order, will authenticate a replacement Note if the Trustee’s requirements are met. If required by the Trustee or the Issuer, an indemnity bond must be supplied by the Holder that is sufficient in the judgment of the Trustee and the Issuer to protect the Issuer, the Trustee, any Agent and any authenticating agent from any loss that any of them may suffer if a Note is replaced. The Issuer may charge for its expenses in replacing a Note.

Every replacement Note is an additional obligation of the Issuer and will be entitled to all of the benefits of this Indenture equally and proportionately with all other Notes duly issued hereunder.

Section 2.08 Outstanding Notes.

The Notes outstanding at any time are all the Notes authenticated by the Trustee except for those canceled by it, those delivered to it for cancellation, those reductions in the interest in a Global Note effected in accordance with the provisions hereof, and those described in this Section 2.08 as not outstanding. Except as set forth in Section 2.09, a Note does not cease to be outstanding because the Issuer or an Affiliate of the Issuer holds the Note; however, Notes held by the Issuer or an Affiliate of the Issuer shall not be deemed to be outstanding for purposes of Section 3.07.

If a Note is replaced pursuant to Section 2.07, it ceases to be outstanding unless the Trustee receives proof satisfactory to it that the replacement Note is held by a “protected purchaser” under the UCC.

If the principal amount of any Note is considered paid under Section 4.01, it ceases to be outstanding and interest on it ceases to accrue.

If the Paying Agent (other than the Issuer, a Subsidiary or an Affiliate of any thereof) holds, on a redemption date or maturity date, money sufficient to pay Notes payable on that date, then on and after that date such Notes will be deemed to be no longer outstanding and will cease to accrue interest.

Section 2.09 Treasury Notes.

In determining whether the Holders of the required principal amount of Notes have concurred in any direction, waiver or consent, Notes owned by the Issuer or any Guarantor, or by any Person directly or indirectly controlling or controlled by or under direct or indirect common control with the Issuer or any Guarantor, will be considered as though not outstanding, except that for the purposes of determining whether the Trustee will be protected in relying on any such direction, waiver or consent, only Notes that the Trustee knows are so owned will be so disregarded.

 

71


Section 2.10 Temporary Notes.

Until certificates representing Notes are ready for delivery, the Issuer may prepare and the Trustee, upon receipt of an Authentication Order, will authenticate temporary Notes. Temporary Notes will be substantially in the form of certificated Notes but may have variations that the Issuer considers appropriate for temporary Notes and as may be reasonably acceptable to the Trustee. Without unreasonable delay, the Issuer will prepare and the Trustee will authenticate definitive Notes in exchange for temporary Notes.

Holders of temporary Notes will be entitled to all of the benefits of this Indenture.

Section 2.11 Cancellation.

The Issuer at any time may deliver Notes to the Trustee for cancellation. The Registrar and Paying Agent will forward to the Trustee any Notes surrendered to them for registration of transfer, exchange or payment. The Trustee and no one else will cancel all Notes surrendered for registration of transfer, exchange, payment, replacement or cancellation and will destroy canceled Notes (subject to the record retention requirement of the Exchange Act). Certification of the destruction of all canceled Notes will be delivered to the Issuer. The Issuer may not issue new Notes to replace Notes that it has paid or that have been delivered to the Trustee for cancellation.

Section 2.12 Defaulted Interest.

If the Issuer defaults in a payment of interest on the Notes, it will pay the defaulted interest in any lawful manner plus, to the extent lawful, interest payable on the defaulted interest, to the Persons who are Holders on a subsequent special record date, in each case at the rate provided in the Notes and in Section 4.01. The Issuer will notify the Trustee in writing of the amount of defaulted interest proposed to be paid on each Note and the date of the proposed payment. The Issuer will fix or cause to be fixed each such special record date and payment date; provided that no such special record date may be less than 10 days prior to the related payment date for such defaulted interest. At least 15 days before the special record date, the Issuer (or, upon the written request of the Issuer, the Trustee in the name and at the expense of the Issuer) will deliver Holders a notice that states the special record date, the related payment date and the amount of such interest to be paid.

ARTICLE 3

REDEMPTION AND PREPAYMENT

Section 3.01 Notices to Trustee.

If the Issuer elects to redeem Notes pursuant to the optional redemption provisions of Section 3.07, it must furnish to the Trustee, at least 10 days but not more than 60 days before a redemption date, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes of a series or a satisfaction and discharge of this Indenture pursuant to Article 8 or 12, an Officer’s Certificate setting forth:

 

  (a)

the Section of this Indenture pursuant to which the redemption shall occur;

 

72


  (b)

the redemption date;

 

  (c)

the series, or more than one series, if applicable, of Notes to be redeemed;

 

  (d)

the principal amount of Notes to be redeemed;

 

  (e)

the redemption price; and

 

  (f)

the CUSIP number of the Notes to be redeemed.

Section 3.02 Selection of Notes to Be Redeemed.

If less than all of the Notes are to be redeemed at any time, or less than all of the Notes of a particular series are to be redeemed, the Trustee will select Notes for redemption by lot, on a pro rata basis (provided that, in the case of Global Notes, Global Notes shall be selected for redemption pursuant to the Applicable Procedures) and, if applicable, with such adjustments so that only Notes in denominations of $2,000 or whole multiples of $1,000 in excess thereof will be purchased unless otherwise required by law, Applicable Procedures, or applicable stock exchange requirements; provided that if only Notes of a particular series are to be redeemed, such selection shall be limited to Notes of such series.

No Notes of $2,000 or less can be redeemed in part. In the event of partial redemption, the particular Notes to be redeemed will be selected, unless otherwise provided herein, not less than 10 nor more than 60 days prior to the redemption or purchase date by the Trustee from the outstanding Notes not previously called for redemption.

The Trustee will promptly notify the Issuer in writing of the Notes selected for redemption and, in the case of any Note selected for partial redemption, the principal amount thereof to be redeemed. Notes and portions of Notes selected will be in amounts of $2,000 or whole multiples of $1,000 in excess thereof; except that if all of the Notes of a Holder are to be redeemed, the entire outstanding amount of Notes held by such Holder, even if not in the amount of $2,000 or a whole multiple of $1,000 thereof, shall be redeemed. Except as provided in the preceding sentence, provisions of this Indenture that apply to Notes called for redemption also apply to portions of Notes called for redemption.

Section 3.03 Notice of Redemption.

At least 10 days but not more than 60 days before a redemption date, the Issuer will deliver a notice of redemption to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes of a series or a satisfaction and discharge of this Indenture pursuant to Article 8 or 12.

 

73


The notice will identify the Notes to be redeemed and will state:

(a) the redemption date;

(b) the redemption price, or if not then ascertainable, the manner of calculation thereof;

(c) if any Note is being redeemed in part, the portion of the principal amount of such Note to be redeemed and that, after the redemption date upon surrender of such Note, a new Note or Notes in principal amount equal to the unredeemed portion will be issued in the name of the Holder upon cancellation of the original Note;

(d) the name and address of the Paying Agent;

(e) that Notes called for redemption must be surrendered to the Paying Agent to collect the redemption price;

(f) that, unless the Issuer defaults in making such redemption payment, interest on Notes called for redemption ceases to accrue on and after the redemption date;

(g) the paragraph of the Notes and/or Section of this Indenture pursuant to which the Notes called for redemption are being redeemed;

(h) that no representation is made as to the correctness or accuracy of the CUSIP number, if any, listed in such notice or printed on the Notes; and

(i) any conditions precedent to which the redemption is subject.

At the Issuer’s request, the Trustee will give the notice of redemption in the Issuer’s name and at its expense; provided, however, that the Issuer has delivered to the Trustee, at least 10 days prior to the redemption date (unless a shorter period is acceptable to the Trustee), an Officer’s Certificate requesting that the Trustee give such notice and setting forth the form of notice to be provided.

Any such redemption may, at the Issuer’s discretion, be subject to one or more conditions precedent, including completion of any related Equity Offerings, Change of Control or other transaction. If such redemption is subject to the satisfaction of one or more conditions precedent, the related notice of redemption shall describe each such condition, and if applicable, shall state that, in the Issuer’s discretion, the redemption date may be delayed until such time as any or all such conditions shall be satisfied or waived, or such redemption may not occur and such notice may be rescinded in the event that any or all such conditions shall not have been satisfied or waived by the redemption date, or by the redemption date as so delayed. In addition, the Issuer may provide in such notice that payment of the redemption price and performance of the Issuer’s obligations with respect to such redemption may be performed by another Person (it being understood that any such provision for payment by another Person will not relieve the Issuer and the Guarantors, if any, from their obligations with respect to such redemption in the event such other person fails to do so and all conditions to such redemption, if any, are satisfied).

 

74


Section 3.04 Effect of Notice of Redemption.

Once notice of redemption is delivered in accordance with Section 3.03, Notes called for redemption become irrevocably due and payable on the redemption date at the redemption price, subject to the fourth paragraph of Section 3.03.

Section 3.05 Deposit of Redemption Price.

Prior to 11:00 a.m. (New York City time) on the redemption date, the Issuer shall deposit with the Paying Agent money sufficient to pay the redemption price of and accrued and unpaid interest on all Notes to be redeemed on that redemption date; provided, however, that to the extent any such funds are received by the Paying Agent from the Issuer after such time on such due date, such funds will be distributed to such Persons as promptly as practicable. The Paying Agent shall promptly return to the Issuer any money deposited with such Paying Agent by the Issuer in excess of the amounts necessary to pay the redemption price of, and accrued and unpaid interest on, all Notes to be redeemed.

If the Issuer complies with the provisions of the preceding paragraph, on and after the redemption date, interest will cease to accrue on the Notes or the portions of Notes called for redemption. If a Note is redeemed on or after an interest record date but on or prior to the related Interest Payment Date, then any accrued and unpaid interest shall be paid to the Holder as at the close of business on such record date. If any Note called for redemption is not so paid upon surrender for redemption because of the failure of the Issuer to comply with the preceding paragraph, interest shall be paid on the unpaid principal, from the redemption or purchase date until such principal is paid, and to the extent lawful on any interest not paid on such unpaid principal, in each case at the rate provided in the Notes and in Section 4.01.

Section 3.06 Notes Redeemed or Purchased in Part.

Upon surrender of a Note that is redeemed in part, the Issuer will issue and, upon receipt of an Authentication Order, the Trustee will authenticate for the Holder at the expense of the Issuer a new Note equal in principal amount to the unredeemed portion of the Note surrendered.

Section 3.07 Optional Redemption.

(a) With respect to the 2032 Notes, at any time prior to February 1, 2027, the Issuer may on any one or more occasions redeem up to 40% of the aggregate principal amount of the 2032 Notes issued under this Indenture prior to the redemption date, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 109.875% of the principal amount of the 2032 Notes redeemed, plus accrued and unpaid interest, if any, to the redemption date with an amount not to exceed the amount of net cash proceeds of one or more Equity Offerings consummated after the Issue Date; provided that:

(1) at least 50% of the aggregate principal amount of 2032 Notes issued under this Indenture on the Issue Date (excluding 2032 Notes held by the Issuer and its Subsidiaries) remains outstanding immediately after the occurrence of such redemption (unless all such 2032 Notes are otherwise repurchased or redeemed pursuant to another provision described under this Article 3); and

 

75


(2) the redemption occurs within 180 days of the date of the closing of such Equity Offering.

(b) At any time prior to November 1, 2028 (in respect of the 2029 Notes) and February 1, 2027 (in respect of the 2032 Notes), the Issuer may on any one or more occasions redeem all or any part of the Notes of a series upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 100% of the principal amount of the Notes redeemed, plus the Applicable Redemption Premium as of, and accrued and unpaid interest, if any, to the date of redemption.

(c) With respect to the 2029 Notes, on or after November 1, 2028, the Issuer may on any one or more occasions redeem all or any part of the 2029 Notes, upon not less than 10 nor more than 60 days’ notice, at a redemption price (expressed as a percentage of principal amount of the 2029 Notes) equal to 100.000%, plus accrued and unpaid interest, if any, to the applicable redemption date.

(d) With respect to the 2032 Notes, on or after February 1, 2027, the Issuer may on any one or more occasions redeem all or any part of the 2032 Notes, upon not less than 10 nor more than 60 days’ notice, at the redemption prices (expressed as a percentage of principal amount of the 2032 Notes) set forth below, plus accrued and unpaid interest, if any, to the applicable redemption date, if redeemed during the twelve-month period beginning on February 1 of the years indicated below:

2032 Notes

 

Year

   Percentage  

2027

     104.938%  

2028

     102.469%  

2029 and thereafter

     100.000%  

Unless the Issuer defaults in the payment of the redemption price, interest will cease to accrue on the Notes of a series or portions thereof called for redemption on the applicable redemption date.

(e) Any redemption pursuant to this Section 3.07 shall be made pursuant to the provisions of Sections 3.01 through 3.06 hereof.

(f) Notwithstanding the foregoing, in connection with any tender offer for any series of Notes, including a Change of Control Offer or Asset Sale Offer for the Notes, if Holders of not less than 90% in aggregate principal amount of the then outstanding Notes of any series validly tender and do not validly withdraw such Notes in such offer and the Issuer, or any third party making such offer in lieu of the Issuer, purchase all of the Notes of such series validly tendered and not validly withdrawn by such Holders, all of the Holders of the Notes of such series will be deemed to have consented to such tender or other offer, and accordingly the Issuer or such third party will have the right upon not less than 10 nor more than 60 days’ prior notice, given not more than 15 days following such purchase date, to redeem all Notes of such series that remain

 

76


outstanding following such purchase at a price equal to the price offered to each other Holder in such offer (which may be less than par) plus, to the extent not included in the offer payment, accrued and unpaid interest, if any, thereon, to, but excluding, the redemption date, subject to the right of Holders of record on the relevant record date to receive interest due on the relevant Interest Payment Date falling prior to or on the redemption date. In determining whether the Holders of at least 90% of the aggregate principal amount of the then outstanding Notes of the applicable series have validly tendered and not validly withdrawn Notes in a tender offer for any series of Notes, including a Change of Control Offer or Asset Sale Offer, as applicable, Notes owned by an Affiliate of the Issuer or by funds controlled or managed by any Affiliate of the Issuer, or any successor thereof, shall be deemed to be outstanding for the purposes of such tender offer for any series of Notes, including a Change of Control Offer or Asset Sale Offer, as applicable.

Section 3.08 Mandatory Redemption; Purchases of Notes.

The Issuer will not be required to make any mandatory redemption or sinking fund payments with respect to the Notes. The Issuer, the Restricted Subsidiaries and their respective Affiliates may at any time and from time to time purchase the Notes in the open market, by tender offer, in negotiated transactions or otherwise.

Section 3.09 Offer to Purchase by Application of Excess Proceeds.

(a) In the event that, pursuant to Section 4.10 hereof, the Issuer shall be required to commence a Collateral Asset Sale Offer or an Asset Sale Offer, or if the Issuer shall elect to commence a Collateral Advance Offer or Advance Offer, the Issuer shall follow the procedures specified below.

(b) The Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall remain open for a period of 20 Business Days following its commencement and no longer, except to the extent that a longer period is required by applicable law (the “Offer Period”). No later than five Business Days after the termination of the Offer Period (the “Purchase Date”), the Issuer shall apply all Collateral Excess Proceeds or Excess Proceeds, as the case may be (the “Offer Amount”), to the purchase of Notes and, if required or permitted by the terms thereof, to other First Lien Obligations (in the case of Collateral Excess Proceeds) or to any other Senior Indebtedness (in the case of Excess Proceeds) (on a pro rata basis, if applicable, with adjustments as necessary so that no Notes or other First Lien Obligations or Senior Indebtedness, as the case may be, will be repurchased in part in an unauthorized denomination), or, if less than the Offer Amount has been tendered, all Notes and other First Lien Obligations (in the case of Collateral Excess Proceeds), or all Notes and any other Senior Indebtedness (in the case of Excess Proceeds), in each case, tendered in response to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be. Payment for any Notes so purchased shall be made in the same manner as interest payments are made.

(c) If the Purchase Date is on or after a record date and on or before the related Interest Payment Date, any accrued and unpaid interest, if any, up to but excluding the Purchase Date shall be paid to the Holder at the close of business on such record date, and no additional interest shall be payable to Holders who tender Notes pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be.

 

77


(d) Upon the commencement of a Collateral Asset Sale Offer, a Collateral Advance Offer, an Asset Sale Offer or an Advance Offer, as the case may be, the Issuer shall send, electronically or by first-class mail, a notice to each of the Holders, with a copy to the Trustee. The notice shall contain all instructions and materials necessary to enable such Holders to tender Notes pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be. The Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall be made to all Holders and, if required or permitted by the terms thereof, holders of other First Lien Obligations (in the case of Collateral Excess Proceeds) or any other Senior Indebtedness (in the case of Excess Proceeds). The notice, which shall govern the terms of the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall state:

(1) that the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, is being made pursuant to this Section 3.08 and Section 4.10 hereof and the length of time the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall remain open;

(2) the Offer Amount, the purchase price and the Purchase Date;

(3) that any Note not tendered or accepted for payment shall continue to accrue interest;

(4) that, unless the Issuer defaults in making such payment, any Note accepted for payment pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall cease to accrue interest on and after the Purchase Date;

(5) that any Holder electing to have less than all of the aggregate principal amount of its Notes purchased pursuant to a Collateral Asset Sale Offer, a Collateral Advance Offer, an Asset Sale Offer or an Advance Offer, as the case may be, may elect to have Notes purchased in integral multiples of $1,000;

(6) that Holders electing to have a Note purchased pursuant to any Collateral Asset Sale Offer, Collateral Advance Offer, Asset Sale Offer or Advance Offer, as the case may be, shall be required to surrender the Note, with the form entitled “Option of Holder to Elect Purchase” attached to the Note completed, or transfer such Note by book-entry transfer, to the Issuer, the applicable Depositary, if appointed by the Issuer, or a Paying Agent at the address specified in the notice at least two Business Days before the Purchase Date;

(7) that Holders shall be entitled to withdraw their election if the Issuer, the applicable Depositary or the Paying Agent, as the case may be, receives, not later than the close of business on the tenth Business Day prior to the expiration date of the Offer Period, a facsimile transmission or letter setting forth the name of the Holder, the principal amount of the Note the Holder delivered for purchase and a statement that such Holder is withdrawing his election to have such Note purchased;

 

78


(8) that, if the aggregate principal amount of Notes and, if applicable, other First Lien Obligations (in the case of Collateral Excess Proceeds) or any other senior Indebtedness (in the case of Excess Proceeds), in each case, surrendered by the holders thereof exceeds the Offer Amount (or, in the case of an Collateral Advance Offer or an Advance Offer, the Collateral Advance Portion or Advance Portion, respectively), the Issuer shall purchase such Notes (subject to Applicable Procedures as to Global Notes) and such other First Lien Obligations or Senior Indebtedness, as the case may be, on a pro rata basis based on the aggregate principal amount (or accreted value, if applicable) of the Notes or such other First Lien Obligations or Senior Indebtedness, as the case may be, tendered (with such adjustments as may be deemed appropriate by the Issuer so that only Notes in integral multiples of $1,000 are purchased); and

(9) that Holders whose certificated Notes were purchased only in part shall be issued new Notes equal in principal amount to the unpurchased portion of the Notes surrendered (or transferred by book-entry transfer) representing the same Indebtedness to the extent not repurchased; provided that new Notes will only be issued in denominations of $2,000 and in integral multiples of $1,000 in excess thereof.

The notice, if delivered electronically or mailed in a manner herein provided, shall be conclusively presumed to have been given, whether or not the Holder receives such notice. If (i) the notice is delivered or mailed in a manner herein provided and (ii) any Holder fails to receive such notice or a Holder receives such notice but it is defective, such Holder’s failure to receive such notice or such defect shall not affect the validity of the proceedings for the purchase of the Notes as to all other Holders that properly received such notice without defect.

(e) On or before the Purchase Date, the Issuer shall, to the extent lawful, (1) accept for payment, on a pro rata basis as described in clause (d)(8) of this Section 3.09, the Offer Amount of Notes or portions thereof validly tendered pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, or if less than the Offer Amount has been tendered, all Notes tendered and (2) deliver or cause to be delivered to the Trustee the Notes properly accepted, together with an Officer’s Certificate stating the aggregate principal amount of Notes or portions thereof so tendered.

(f) The Issuer, the Depositary or the Paying Agent, as the case may be, shall promptly deliver to each tendering Holder an amount equal to the purchase price of the Notes properly tendered by such Holder and accepted by the Issuer for purchase, and the Issuer shall promptly issue a new Note, and the Trustee, upon receipt of an Authentication Order, shall authenticate and mail or deliver (or cause to be transferred by book-entry) such new Note to such Holder (it being understood that, notwithstanding anything in this Indenture to the contrary, only an Officer’s Certificate and not an Opinion of Counsel is required for the Trustee to authenticate and deliver such new Note) in a principal amount equal to any unpurchased portion of the Note surrendered representing the same Indebtedness to the extent not repurchased; provided, that each such new Note shall be in a principal amount of $2,000 or an integral multiple of $1,000 in excess thereof.

 

79


Any Note not so accepted shall be promptly mailed or delivered by the Issuer to the Holder thereof. The Issuer shall announce the results of the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, on or as soon as practicable after the Purchase Date on the website or online data system maintain pursuant to Section 4.03(a) hereof.

(g) Prior to 11:00 a.m. (New York City time) on the Purchase Date, the Issuer shall deposit with the Paying Agent money sufficient to pay the purchase price of and accrued and unpaid interest on all Notes to be purchased on that Purchase Date; provided, however, that to the extent any such funds are received by the Paying Agent from the Issuer after such time on such due date, such funds will be distributed to such Persons as promptly as practicable. The Paying Agent shall promptly return to the Issuer any money deposited with the Paying Agent by the Issuer in excess of the amounts necessary to pay the purchase price of, and accrued and unpaid interest on, all Notes to be redeemed.

Other than as specifically provided in this Section 3.08 or Section 4.10 hereof, any purchase pursuant to this Section 3.08 shall be made pursuant to the applicable provisions of Sections 3.01 through 3.06 hereof, and references therein to “redeem,” “redemption,” “Redemption Date” and similar words shall be deemed to refer to “purchase,” “repurchase,” “Purchase Date” and similar words, as applicable.

ARTICLE 4

COVENANTS

Section 4.01 Payment of Notes.

The Issuer will pay or cause to be paid the principal of, premium, if any, and interest, if any, on, the Notes of each series on the dates and in the manner provided in the Notes of each series. Principal, premium, if any, and interest, if any, will be considered paid on the date due if the Paying Agent, if other than the Issuer or a Subsidiary thereof, holds as of 11:00 a.m. (New York City time) on the due date money deposited by the Issuer in immediately available funds and designated for and sufficient to pay all principal, premium, if any, and interest, if any, then due.

Section 4.02 Maintenance of Office or Agency.

The Issuer will maintain in the Borough of Manhattan, the City of New York, an office or agency (which may be an office of the Trustee or an Affiliate of the Trustee, Registrar or co-registrar) where Notes may be surrendered for registration of transfer or for exchange and where notices and demands to or upon the Issuer in respect of the Notes and this Indenture may be served. The Issuer will give prompt written notice to the Trustee of the location, and any change in the location, of such office or agency. If at any time the Issuer fails to maintain any such required office or agency or fails to furnish the Trustee with the address thereof, such presentations, surrenders, notices and demands may be made or served at the Corporate Trust Office of the Trustee.

 

80


The Issuer may also from time to time designate one or more other offices or agencies where the Notes may be presented or surrendered for any or all such purposes and may from time to time rescind such designations; provided, however, that no such designation or rescission will in any manner relieve the Issuer of its obligation to maintain an office or agency in the Borough of Manhattan, the City of New York for such purposes. The Issuer will give prompt written notice to the Trustee of any such designation or rescission and of any change in the location of any such other office or agency.

The Issuer hereby designates the Corporate Trust Office of the Trustee as one such office or agency of the Issuer in accordance with Section 2.03.

Section 4.03 Reports.

The Issuer will deliver to the Trustee and make available to the Holders of the Notes, without cost to the Trustee or any Holder:

(a) within 120 days after the end of each fiscal year of the Issuer, an annual report containing, to the extent applicable, the following information:

(1) audited consolidated balance sheets of the Issuer and audited consolidated income statements and audited statements of cash flow of the Issuer as of and for the two most recent fiscal years, including appropriate footnotes to such financial statements, audited by an internationally recognized firm of independent public accountants, and the report of the independent public accountants of the Issuer on such financial statements; and

(2) a “management’s discussion and analysis” of the results of operations of the Issuer and its Subsidiaries on a consolidated basis for the periods presented in a level of detail comparable to the management’s discussion and analysis of the results of operations contained in the Offering Memorandum;

(b) within 60 days after the end of the first three fiscal quarters in each fiscal year of the Issuer, a quarterly report containing, to the extent applicable, the following information:

(1) an unaudited condensed consolidated balance sheet of the Issuer as of the end of such fiscal quarter and unaudited condensed statements of income and cash flow for the most recent fiscal interim period ending on the date of the unaudited condensed balance sheet, and the comparable prior year period (or comparable prior year end, in the case of such balance sheet), together with condensed footnote disclosure; and

(2) a “management’s discussion and analysis” of the results of operations of the Issuer and its Subsidiaries on a consolidated basis for the periods presented in a level of detail comparable to the management’s discussion and analysis of the results of operations contained in the Offering Memorandum;

(c) within 10 Business Days after the occurrence of any event that would require a filing with the Commission on Form 8-K under Items 1.03, 2.01 (only with respect to acquisitions that the Issuer determines in good faith are material to holders of the Notes), 4.01, 4.02(a) and (b), 5.01 and 5.02(b) (with respect to the principal executive officer, president, principal financial officer, principal accounting officer and principal operating officer only) as in effect as of the Issue Date, a notice or report containing a brief description of such event.

 

81


All such annual and quarterly financial statements will be prepared in accordance with GAAP (with the absence of year-end adjustments in the case of quarterly financial statements). For the avoidance of doubt, no report needs to include separate financial statements for the Issuer, any Guarantor or any Subsidiary that is not a Guarantor.

Notwithstanding the foregoing, with respect to any financial statements, reports, information and other disclosures provided in clauses (a) through (c) above, such (A) such financial statements, reports, information and other disclosures shall not be required to include as an exhibit, or to include a summary of the terms of, any employment or compensatory arrangement, agreement, plan or understanding between the Issuer (or any Parent Entity or Subsidiaries of the Issuer) and any director, manager or officer, of the Issuer (or any Parent Entity or Subsidiaries of the Issuer), (B) the Issuer shall not be required to make available any information regarding the occurrence of any of the events set forth in clause (c) above if the Issuer determines in its good faith judgment that the event that would otherwise be required to be disclosed is not material to the holders of the Notes or the business, assets, operations, financial positions or prospects of the Issuer and its Restricted Subsidiaries taken as a whole, (C) no such financial statements, reports, information or other disclosures will be required to comply with Regulation G under the Exchange Act or Item 10(e) of Regulation S-K with respect to any “non-GAAP” financial information contained therein, (D) no such report will be required to comply with Regulation S-K or Regulation S-X including, without limitation, Rules 3-05, 3-09, 3-10, 3-16, 13-01, 13-02 or Article 11 thereof, (E) no such financial statements, reports, information or other disclosures will be required to provide any information that is not otherwise similar to information currently included in the Offering Memorandum, (F) in no event will such financial statements, reports, information or other disclosures be required to include as an exhibit copies of any agreements, financial statements or other items that would be required to be filed as exhibits under the Commission rules, (G) trade secrets and other information that could, in the Issuer’s good faith judgment, cause competitive harm to the Issuer and its Subsidiaries may be excluded from any such financial statements, reports, information or other disclosures, (H) such financial statements or information will not be required to contain any “segment reporting,” (I) such financial statements and information may, at the election of the Issuer, be prepared in accordance with GAAP or IFRS, (J) the Issuer may elect to change its fiscal year end, and (K) no acquired business financial statements or pro forma financial statements shall be required to be disclosed.

If the Issuer or any Parent Entity does not file reports containing such information with the SEC, then the Issuer shall make available such financial statements, reports, information and other disclosures to any Holder, in each case by posting such information on a password-protected website or online data system which shall require a confidentiality acknowledgment, and will make such information readily available to any bona fide prospective investor who agrees to treat such information as confidential; provided that the Issuer shall post such financial statements, reports, information and other disclosures thereon and make readily available any password or other login information to any such bona fide prospective investor; provided, however, that the Issuer may deny access to any competitively-sensitive information otherwise to be provided pursuant to this Section 4.03 to any such Holder or bona fide prospective investor to the extent that the Issuer determines in good faith that the provision of such information to such Person would be competitively harmful to the Issuer and its Subsidiaries; and provided, further, that such Holders and bona fide prospective investors shall agree to (A) treat all such financial statements, reports, information and other disclosures as confidential, (B) not to use such financial statements, reports, information and other disclosures for any purpose other than their investment or potential investment in the Notes and (C) not publicly disclose any such financial statements, reports, information and other disclosures.

 

82


To the extent not satisfied by this Section 4.03, the Issuer shall furnish to holders of Notes and prospective investors, upon their request, any information required to be delivered pursuant to Rule 144A(d)(4) under the Securities Act so long as the Notes are not freely transferable under the Securities Act by persons who are not “affiliates” as defined under the Securities Act.

Notwithstanding the foregoing, the Issuer may satisfy its obligations in this Section 4.03 with respect to financial information relating to the Issuer by furnishing financial information relating to any Parent Entity; provided that, if such financial information relates to any such Parent Entity that is not a Guarantor, then the same is accompanied by selected financial metrics that show the differences (in the Issuer’s sole discretion) between the information relating to such Parent Entity, on the one hand, and the information relating to the Issuer and its Subsidiaries on a standalone basis, on the other hand.

The Issuer shall use its commercially reasonable efforts to participate in quarterly conference calls (which may be a single conference call together with investors and lenders holding other securities or Indebtedness of the Issuer, its Restricted Subsidiaries and/or any direct or indirect parent of the Issuer) to discuss results of operations. The conference call will be following the last day of each fiscal quarter of the Issuer within a reasonable period of time following the time that the Issuer distributes the financial information as set forth in clauses (a) and (b) above. Prior to the conference call, the Issuer will issue a press release or otherwise announce (including, for the avoidance of doubt, by posting an announcement to a password-protected website or online data system through which information described in this Section 4.03 is provided) the time and date of such conference call and provide instructions for holders of Notes, prospective investors in the Notes, securities analysts and market making financial institutions to obtain access to such call.

To the extent any information is not provided within the time periods specified in this Section 4.03 and such information is subsequently provided, the Issuer will be deemed to have satisfied its obligations with respect thereto at such time and any Default with respect thereto shall be deemed to have been cured.

The Trustee shall not be obligated or under any duty to monitor or confirm, on a continuing basis or otherwise, the Issuer’s compliance with the covenants or with respect to any reports or other documents posted to Intralinks or another password protected website or data system or filed with the Commission or EDGAR or any website, or to participate in any conference calls.

The delivery of such reports, information and documents to the Trustee is for informational purposes only and the Trustee’s receipt of such shall not constitute actual or constructive notice of any information contained therein or determinable from information contained therein, including the Issuer’s compliance with any of its covenants in this Indenture (as to which the Trustee is entitled to rely exclusively on Officer’s Certificates).

 

83


Section 4.04 Compliance Certificate.

(a) The Issuer shall deliver to the Trustee, within 120 days after the end of each fiscal year of the Issuer and, if timely, accompanying the annual financial statements as described in Section 4.03 of this Indenture, a statement regarding compliance with this Indenture in an Officer’s Certificate also confirming that, to the signing officer’s knowledge, no Event of Default or Default has occurred and is continuing which has not been waived, or, if the same has occurred, a description of any measures taken or proposed to be taken by the Issuer to address the same.

(b) So long as any of the Notes are outstanding, the Issuer will deliver to the Trustee, within 20 Business Days of any of their Officers becoming aware of any Default or Event of Default, an Officer’s Certificate specifying such Default or Event of Default and what action the Issuer is taking or propose to take with respect thereto, but only to the extent such Default or Event of Default has not been cured by the end of such 20 Business Day period.

Section 4.05 Taxes.

Each of the Issuer and its respective Restricted Subsidiaries (or, for the purposes of this Section 4.05, if such entity is a disregarded entity for U.S. federal income tax purposes, its owner for U.S. federal income tax purposes) will pay or cause to be paid all material Taxes (if any) imposed on it or its property by any Governmental Authority, when due, giving effect to any applicable extensions, unless these are being contested in good faith and by appropriate proceedings and an appropriate reserve has been established in respect thereof in accordance with GAAP.

Section 4.06 Stay, Extension and Usury Laws.

The Issuer and each of the Guarantors covenants (to the extent that it may lawfully do so) that it will not at any time insist upon, plead, or in any manner whatsoever claim or take the benefit or advantage of, any stay, extension or usury law wherever enacted, now or at any time hereafter in force, that may affect the covenants or the performance of this Indenture; and the Issuer and each of the Guarantors (to the extent that it may lawfully do so) hereby expressly waives all benefit or advantage of any such law, and covenants that it will not, by resort to any such law, hinder, delay or impede the execution of any power herein granted to the Trustee, but will suffer and permit the execution of every such power as though no such law has been enacted.

Section 4.07 Limitation on Restricted Payments.

(a) The Issuer will not, and will not permit any of its Restricted Subsidiaries to, directly or indirectly:

(1) declare or pay any dividend or make any other payment or distribution on account of the Issuer’s or any of its Restricted Subsidiaries’ Equity Interests (including, without limitation, any payment in connection with any merger or consolidation involving the Issuer or its Restricted Subsidiaries) or to the direct or indirect holders of the Issuer’s or any of its Restricted Subsidiaries’ Equity Interests in their capacity as holders (other than dividends or distributions payable in Equity Interests (other than Disqualified Stock) of the Issuer or any of its Restricted Subsidiaries and other than dividends or distributions payable to the Issuer or its Restricted Subsidiaries on at least a pro rata basis);

 

84


(2) purchase, redeem or otherwise acquire or retire for value (including, without limitation, in connection with any merger or consolidation involving the Issuer) any Equity Interests of the Issuer or any Parent Entity other than Equity Interests held by the Issuer or any of its Restricted Subsidiaries;

(3) make any principal payment on, or purchase, repurchase, redeem, defease or otherwise acquire or retire for value, prior to scheduled maturity, scheduled repayment or scheduled sinking fund payment, any subordinated Indebtedness (excluding any intercompany Indebtedness between or among the Issuer and any of its Restricted Subsidiaries), except (i) a payment of principal at the Stated Maturity thereof or (ii) the purchase, repurchase, redemption, defeasance or other acquisition or retirement for value of any subordinated Indebtedness in anticipation of satisfying a sinking fund obligation, principal installment or payment at final maturity, in each case due within one year of the date of purchase, repurchase, redemption, defeasance or other acquisition or retirement for value; or

(4) make any Restricted Investment in any Person,

(all such payments and other actions set forth in clauses (1) through (4) above being collectively referred to as “Restricted Payments”), unless, at the time of any such Restricted Payment, no Event of Default has occurred and is continuing or would occur as a consequence of such Restricted Payment, and:

(A) if the Fixed Charge Coverage Ratio for the applicable Test Period at the time of such Restricted Payment is greater than or equal to 1.75 to 1.00, such Restricted Payment, together with the aggregate amount of all other Restricted Payments made by the Issuer and its Restricted Subsidiaries since the Reference Date (excluding Restricted Payments permitted by clauses (2) through (23) of Section 4.07(b)), is less than the sum, without duplication, of:

(i) Cumulative Distributable Cash, determined as of the date such Restricted Payment is made; plus

(ii) 100% of the aggregate net cash proceeds and the Fair Market Value of marketable securities and other property received by the Issuer since the Reference Date (x) as a contribution to its common equity capital or (y) in consideration of the sale or issuance of Equity Interests of the Issuer (other than Disqualified Stock or Designated Preferred Stock) or from the issue or sale of convertible or exchangeable Disqualified Stock of the Issuer or convertible or exchangeable Indebtedness of the Issuer, in each case that have been converted into or exchanged for Equity Interests of the Issuer or any Parent Entity (other than Equity Interests (or Disqualified Stock or convertible or exchangeable Indebtedness) sold to a Subsidiary of the Issuer); plus

(iii) the aggregate amount of Retained Asset Sale Proceeds and Declined Excess Proceeds since the Reference Date; plus

 

85


(iv) to the extent that any Restricted Investment that was made after the Reference Date is sold for cash or otherwise liquidated or repaid for cash, 100% of the aggregate amount received by the Issuer or its Restricted Subsidiaries in cash and the Fair Market Value of property other than cash received; plus

(v) the net reduction in Restricted Investments after the Reference Date resulting from dividends, liquidating distributions, redemptions, repayments of loans or advances, or other transfers of assets in each case to the Issuer or any of its Restricted Subsidiaries from any Person (including, without limitation, Unrestricted Subsidiaries and Joint Ventures) or from redesignation of Unrestricted Subsidiaries as Restricted Subsidiaries; plus

(vi) $2.0 billion,

in the case of each of the foregoing items (ii) through (v) for purposes of this clause (A), to the extent such amounts have not been included in Cumulative Distributable Cash for any period commencing on or after the Reference Date (such items (ii) through (v) being referred to collectively as “Incremental Funds); minus

(vii) the aggregate amount of Incremental Funds previously expended pursuant to this clause (A) or clause (B) below; or

(B) if the Fixed Charge Coverage Ratio for the applicable Test Period at the time of such Restricted Payment is less than 1.75 to 1.00, such Restricted Payment, together with the aggregate amount of all other Restricted Payments made by the Issuer and its Restricted Subsidiaries during the quarter in which such Restricted Payment is made (excluding Restricted Payments permitted by clauses (2) through (19) of Section 4.07(b)) is less than the sum, without duplication, of:

(i) the greater of (x) $2.0 billion and (y) 60.0% of Distributable Cash for the applicable Test Period, less the aggregate amount of all Restricted Payments made by the Issuer and its Restricted Subsidiaries pursuant to this clause (B)(i) during the period beginning on the Reference Date and ending on the last day of the fiscal quarter immediately preceding the quarter in which such Restricted Payment is made; plus

(ii) Incremental Funds to the extent such amounts have not previously been expended pursuant to this clause (B) or clause (A) above (including any amounts that were included in Cumulative Distributable Cash for any period commencing on or after the Reference Date and expended pursuant to clause (A) above).

(b) The preceding provisions will not prohibit:

(1) the payment of any dividend or the consummation of any redemption within 60 days after the date of declaration of the dividend or giving of the redemption notice, as the case may be, if at the date of declaration or notice, the dividend or redemption payment would have complied with this Indenture;

 

86


(2) the making of any Restricted Payment in exchange for, or out of or with the net cash proceeds of the substantially concurrent sale or issuance (other than to a Subsidiary of the Issuer) of, Equity Interests of the Issuer (other than Disqualified Stock), or from the substantially concurrent contribution to the common equity capital of the Issuer (other than from a Subsidiary of the Issuer); provided that the amount of any net cash proceeds that are utilized for any such Restricted Payment will not be or not have been included in Incremental Funds;

(3) the repurchase, redemption or other acquisition or retirement for value of any Equity Interests of the Issuer held by any future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or any of its Restricted Subsidiaries pursuant to any equity subscription agreement, stock option agreement, restricted stock grant, shareholders’ agreement or similar agreement; provided that the aggregate price paid for all such repurchased, redeemed, acquired or retired Equity Interests may not exceed $50 million in any calendar year (with unused amounts in any calendar year being carried over to succeeding calendar years); and provided further, that such amount in any calendar year may be increased by an amount not to exceed the cash proceeds from (i) the sale of Equity Interests of the Issuer received by the Issuer or a Restricted Subsidiary during such calendar year, in each case to any future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or any of its Restricted Subsidiaries (to the extent not included in Incremental Funds) and (ii) key man life insurance policies received by the Issuer or any of its Restricted Subsidiaries in such calendar year;

(4) the defeasance, redemption, repurchase, repayment or other acquisition of subordinated Indebtedness with the net cash proceeds from an incurrence of Refinancing Indebtedness;

(5) the repurchase, redemption or other acquisition or retirement for value of any Preferred Stock, any Disqualified Stock or any subordinated Indebtedness pursuant to provisions similar to those described in Sections 4.10 and 4.15 hereof; provided that all Notes tendered by Holders of the Notes in connection with a Change of Control Offer or Asset Sale Offer, as applicable, have been repurchased, redeemed or acquired for value;

(6) [reserved];

(7) [reserved];

(8) the declaration and payment of regularly scheduled or accrued dividends to holders of any class or series of Disqualified Stock of the Issuer or its Restricted Subsidiaries or any Preferred Equity of any Restricted Subsidiary (other than the Issuer or the Guarantors) issued on or after the Reference Date in accordance with Section 4.09;

(9) payments of cash, dividends, distributions, advances or other Restricted Payments by the Issuer or any of its Restricted Subsidiaries to allow the payment of cash in lieu of the issuance of fractional shares upon the exercise of options, warrants or similar securities or the conversion or exchange of Capital Stock of any such Person;

 

87


(10) (i) the declaration and payment of dividends to holders of any class or series of Designated Preferred Stock (other than Disqualified Stock) issued by the Issuer after the Reference Date; provided that for the applicable Test Period, after giving effect to such issuance or declaration on a pro forma basis, the Issuer could incur $1.00 of additional Indebtedness pursuant to Section 4.09(a); and (ii) the declaration and payment of dividends to any Parent Entity, the proceeds of which will be used to fund the payment of dividends to holders of any class or series of Designated Preferred Stock (other than Disqualified Stock) issued by such Parent Entity after the Reference Date; provided that the amount of dividends paid pursuant to this subclause (ii) shall not exceed the aggregate amount of cash actually contributed to the Issuer from the sale of such Designated Preferred Stock;

(11) the payment of any dividend (or, in the case of any partnership or limited liability company, any similar distribution) by a Restricted Subsidiary to the holders of its Equity Interests in accordance with the charter, partnership agreement, limited liability company agreement or other governing documents of such Restricted Subsidiary or on a pro rata basis or a more favorable basis to the Issuer or the Restricted Subsidiary that is the parent of the Restricted Subsidiary making such payment;

(12) any payments pursuant to clauses (19) through (21) of Section 4.11(b)(19);

(13) additional Restricted Payments made after the Issue Date in an aggregate amount pursuant to this clause (13) not to exceed the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period;

(14) other Restricted Payments, so long as the Holdco Debt Ratio is no greater than 0.95 to 1.0 determined on a pro forma basis for the applicable Test Period; provided, however, that at the time of, and after giving effect to, any Restricted Payment permitted under this clause (14), no Event of Default shall have occurred and be continuing or would otherwise occur as a consequence thereof;

(15) the purchase by the Issuer of fractional shares arising out of stock dividends, splits or combinations or business combinations and payments or distributions to dissenting stockholders pursuant to applicable law in connection with a consolidation, merger or transfer of assets;

(16) dividends or other distributions by the Issuer or any Restricted Subsidiary of (x) Capital Stock of an Unrestricted Subsidiary, or (y) Indebtedness owed to the Issuer or a Restricted Subsidiary by, an Unrestricted Subsidiary, in each case, other than an Unrestricted Subsidiary the principal asset of which is (i) cash and Cash Equivalents or (ii) intellectual property that is material to the Issuer and its Subsidiaries, taken as a whole;

(17) any prepayment, redemption, purchase, repurchase or defeasance of Equity Interests or subordinated Indebtedness pursuant to a Permitted Transaction;

 

88


(18) any prepayment, redemption, purchase, repurchase or defeasance of any Equity Interests (i) pursuant to any definitive agreement in effect as of the Reference Date and (ii) up to an additional aggregate amount pursuant to this clause (18) not to exceed $1.5 billion;

(19) the defeasance, redemption, repurchase, repayment or other acquisition of subordinated Indebtedness that constitutes a Non-Recourse Financing;

(20) (i) the declaration and payment of dividends on the common stock or common Equity Interests of the Issuer or any Parent Entity (and any equivalent declaration and payment of a distribution of any security exchangeable for such common stock or common Equity Interests to the extent required by the terms of any such exchangeable securities and any Restricted Payment to any such Parent Entity to fund the payment by such Parent Entity of dividends on such entity’s Capital Stock), following a public offering of such common stock or common Equity Interests (or such exchangeable securities, as applicable), in an amount in any fiscal year not to exceed the sum of (A) 7% of the amount of net cash proceeds received by or contributed to the Issuer or any of its Restricted Subsidiaries from any such public offering and (B) 7% of Market Capitalization; or (ii) in lieu of all or a portion of the dividends permitted by subclause (i), any prepayment, purchase, repurchase, redemption, defeasance, discharge, retirement or other acquisition of the Issuer’s Capital Stock (and any equivalent prepayment, purchase, repurchase, redemption, defeasance, discharge, retirement or other acquisition of any security exchangeable for such common stock or common equity interests to the extent required by the terms of any such exchangeable securities and any Restricted Payment to any Parent Entity to fund the prepayment, purchase, repurchase, redemption, defeasance, discharge, retirement or other acquisition of such entity’s Capital Stock) for aggregate consideration that, when taken together with dividends permitted by subclause (i), does not exceed the amount contemplated by subclause (i);

(21) Restricted Payments made in connection with or relating to, and deemed reasonably necessary by the Issuer in good faith for the consummation of, any IPO Reorganization Transactions or Tax Restructuring; provided that if immediately after giving pro forma effect to any such IPO Reorganization Transactions or Tax Restructuring and the transactions to be consummated in connection therewith, any distributed asset ceases to be owned by the Issuer or any Restricted Subsidiary (or any entity ceases to be a Restricted Subsidiary), the applicable portion of such Restricted Payment must be otherwise permitted under another provision of this covenant (and constitute utilization of such other Restricted Payment exception or capacity);

(22) payments made or expected to be made (including repurchases of Capital Stock) by the Issuer or any of its Restricted Subsidiaries in respect of withholding or similar Taxes payable in connection with the exercise or vesting of Capital Stock or any other equity award by any future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or any of its Restricted Subsidiaries or any Parent Entity and purchases, repurchases, redemptions, defeasances or other acquisitions or retirements of Capital Stock deemed to occur upon the exercise, conversion or exchange of stock options, warrants, equity-based awards or other rights in respect thereof if such Capital Stock represents a portion of the exercise price thereof or payments in respect of withholding or similar Taxes payable upon exercise or vesting thereof; and

 

89


(23) distributions or payments made directly or by means of discounts with respect to any participation interest issued or sold in connection with, and other fees paid to a Person that is not a Receivables Subsidiary in connection with, any Permitted Receivables Financing.

(c) The amount of all Restricted Payments (other than cash) shall be the Fair Market Value on the date of such Restricted Payment of the asset(s) or securities proposed to be paid, transferred or issued by the Issuer or such Restricted Subsidiary, as the case may be, pursuant to such Restricted Payment, without giving effect to subsequent changes in value. The Fair Market Value of any cash Restricted Payment shall be its face amount.

(d) For purposes of determining compliance with this Section 4.07, in the event that a proposed Restricted Payment (or a portion thereof) meets the criteria of clauses (1) through (23) of Section 4.07(b) or is entitled to be made pursuant to Section 4.07(a) or as a Permitted Investment, the Issuer will be able to classify or later reclassify (based on circumstances existing on the date of such reclassification) such Restricted Payment (or a portion thereof) between such clauses (1) through (23) of Section 4.07(b) and Section 4.07(a) or as a Permitted Investment in any manner that otherwise complies with this Section 4.07.

(e) For the avoidance of doubt, this Section 4.07 shall not restrict the making of any “AHYDO catch-up payment” with respect to, and required by the terms of, any Indebtedness of the Issuer or any of its Restricted Subsidiaries permitted to be incurred under the terms of this Indenture.

Section 4.08 Limitation on Dividends and Other Payment Restrictions Affecting Restricted Subsidiaries.

(a) The Issuer will not, and will not permit any Restricted Subsidiary to, directly or indirectly, create or otherwise cause or become effective any consensual encumbrance or restriction of any kind on the ability of any Restricted Subsidiary to:

(1) pay dividends, in cash or otherwise, or make any other distributions on or in respect of its Capital Stock or any other interest or participation in, or measured by, its profits;

(2) pay any Indebtedness owed to the Issuer or any other Restricted Subsidiary;

(3) make loans or advances to the Issuer or any other Restricted Subsidiary; or

(4) transfer any of its properties or assets to the Issuer or any other Restricted Subsidiary.

 

90


(b) Section 4.08(a) hereof will not apply to:

(1) encumbrances and restrictions existing under or by reason of the Notes, this Indenture or the Guarantees;

(2) encumbrances and restrictions existing under or by reason of (i) any agreement or instrument relating to, or entered into in connection with, any Project, any Project Obligations, any Permitted Project Undertaking, any Permitted Business Investment, any Permitted Transaction, or any Non-Recourse Financing, in each case that is not prohibited by this Indenture, or (ii) any Project Document;

(3) any encumbrance or restriction arising pursuant to an agreement or instrument relating to any Indebtedness, Disqualified Stock or Preferred Stock permitted to be incurred or issued subsequent to the Issue Date pursuant to Section 4.09 hereof if (i) such encumbrance or restriction will not materially impair the ability of the Issuer and the Guarantors, taken as a whole, to make anticipated principal or interest payments on the Notes (as determined in good faith by the Issuer), (ii) such encumbrances and restrictions are not materially more disadvantageous, taken as a whole, to the holders of the Notes than is customary in comparable financings for similarly situated issuers (as determined in good faith by the Issuer), or (iii) such encumbrances and restrictions apply only during the continuance of a default in respect of a payment or financial maintenance covenant relating to such Indebtedness, Disqualified Stock or Preferred Stock;

(4) any agreement or instrument in effect on the Issue Date, including pursuant to the Existing Notes, the Existing Notes Indenture and the guarantees thereof;

(5) with respect to restrictions or encumbrances referred to in clause (a)(4) of this Section 4.08, encumbrances and restrictions: (i) that restrict in a customary manner the subletting, assignment or transfer of any properties or assets that are subject to a lease, license, conveyance or other similar agreement to which the Issuer or any Restricted Subsidiary is a party; and (ii) contained in Finance Lease Obligations, purchase money obligations or operating leases that impose such restrictions or encumbrances on the property so purchased, leased, expanded, constructed, developed, installed, replaced, relocated, renewed, maintained, upgraded, repaired or improved;

(6) encumbrances or restrictions contained in any agreement or other instrument of (i) a Person acquired by or merged, amalgamated or consolidated with or into the Issuer or any Restricted Subsidiary in effect at the time of such acquisition, merger, amalgamation or consolidation, as applicable or (ii) an Unrestricted Subsidiary, at the time it is designated or deemed to become a Restricted Subsidiary, in each case, which encumbrance or restriction is not applicable to any Person, or the properties or assets of any Person, other than the Person, or the property or assets of the Person, and was not put in place in contemplation of such event;

(7) encumbrances or restrictions contained in contracts for sales of Capital Stock or assets that are not prohibited by Section 4.10 with respect to the assets or Capital Stock to be sold pursuant to such contract or in customary merger or acquisition agreements (or any option to enter into such contract) for the purchase or acquisition of Capital Stock or assets or any of the Issuer’s Subsidiaries by another Person;

 

91


(8) encumbrances or restrictions existing under or by reason of applicable law, regulation or similar restriction or by governmental licenses, concessions, franchises or permits;

(9) encumbrances or restrictions on cash or other deposits or net worth imposed by customers under contracts entered into the ordinary course of business;

(10) customary provisions in joint venture agreements and other similar agreements or arrangements relating to such joint venture (as determined by the Issuer in good faith);

(11) in the case of clause (a)(4) of this Section 4.08, customary encumbrances or restrictions in connection with purchase money obligations, mortgage financings, Finance Lease Obligations and Sale and Leaseback Transactions;

(12) any encumbrance or restriction arising by reason of customary non-assignment provisions;

(13) customary restrictions on fiduciary cash held by the Issuer’s Restricted Subsidiaries;

(14) customary provisions contained in leases, sub-leases, licenses, sub-licenses or similar agreements, including with respect to intellectual property and other agreements;

(15) customary restrictions on the transfer of non-cash assets contained in power purchase agreements and similar agreements;

(16) [reserved];

(17) customary provisions in agreements governing Hedging Obligations;

(18) customary provisions contained in agreements entered into in the ordinary course of business or encumbrances or restrictions existing under or by reason of any Lien permitted to be incurred pursuant to Section 4.12;

(19) encumbrances or restrictions contained in the charter, partnership agreement or limited liability company agreement or other governing documents of a Restricted Subsidiary relating to tax equity or similar financings;

(20) any encumbrance or restriction pursuant to an agreement or instrument effecting a refunding, renewal, replacement or refinancing of Indebtedness incurred pursuant to, or that otherwise extends, renews, refunds, increases, supplements, modifies, refinances or replaces, an agreement, contract, obligation or instrument referred to in clauses (1) through (19) of this Section 4.08(b) or contained in any amendment, supplement or other modification to an agreement referred to in clauses (1) through (19) of this Section 4.08(b); provided, however, that the encumbrances and restrictions with respect to such Restricted Subsidiary contained in any such agreement or instrument (i) are not materially more restrictive, taken as a whole, with respect to such dividend and other payment restrictions than those contained in such agreement or instrument or (ii) will not materially impair the ability of the Issuer and the Guarantors, taken as a whole, to make anticipated principal or interest payments on the Notes (as determined in good faith by the Issuer); or

(21) restrictions created in connection with any Permitted Receivables Financing.

 

92


For purposes of determining compliance with this Section 4.08, (1) the priority of any Preferred Equity in receiving dividends or distributions prior to dividends or distributions being paid on common stock will not be deemed a restriction on the ability to make distributions on Capital Stock and (2) the subordination of loans or advances made to the Issuer or a Restricted Subsidiary to other Indebtedness incurred by the Issuer or any such Restricted Subsidiary will not be deemed a restriction on the ability to make loans or advances.

Section 4.09 Limitation on Indebtedness, Disqualified Stock and Preferred Equity

(a) Subject to the exceptions in Section 4.09(b), the Issuer will not, and will not permit any of its Restricted Subsidiaries to, directly or indirectly, create, incur, issue, assume, guarantee or otherwise become directly or indirectly liable, contingently or otherwise, with respect to (collectively, “incur”) any Indebtedness (including Acquired Debt), and the Issuer will not issue any Disqualified Stock and will not permit any Restricted Subsidiary to issue any Disqualified Stock or any Restricted Subsidiary that is not a Guarantor to issue Preferred Equity; provided, however, that any Recourse Person may incur Indebtedness (including Acquired Debt) or issue Disqualified Stock, and any Recourse Person (other than the Issuer) may issue Preferred Equity, if on the date of incurrence or issuance thereof the Holdco Debt Ratio for the applicable Test Period would have been equal to or less than 5.0 to 1.0, determined on a pro forma basis (including a pro forma application of the net proceeds therefrom), as if the additional Indebtedness had been incurred or the Disqualified Stock or the Preferred Equity had been issued, as the case may be, on the first day of the relevant Test Period.

(b) Section 4.09(a) will not prohibit the incurrence of any of the following items of Indebtedness (collectively, “Permitted Debt”):

(1) Indebtedness of the Issuer or any of its Restricted Subsidiaries under Credit Facilities; provided that, immediately after giving effect to any such incurrence or issuance (including pro forma application of the net proceeds therefrom), the aggregate principal amount of all such Indebtedness pursuant to this clause (1) and that is then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (1) and then outstanding) does not exceed the greater of (A) $2.0 billion and (B) 60.0% of Distributable Cash for the applicable Test Period;

(2) the incurrence by the Issuer and any Guarantor of Indebtedness represented by the Notes of each series (including any Guarantee thereof) (other than any Additional Notes, if any, or Guarantees with respect thereto);

(3) the Existing Indebtedness, including the Existing Notes and the guarantees thereof;

 

93


(4) Indebtedness, Disqualified Stock or Preferred Equity of the Issuer or its Restricted Subsidiaries represented by Finance Lease Obligations, Sale and Leaseback Transactions, mortgage financings or purchase money obligations, or, incurred to finance or refinance the acquisition, purchase, leasing, development, construction, repair, replacement, refurbishment, repositioning, design, installment or improvement of property (real or personal), equipment, or other assets (including Capital Stock), and whether acquired through the direct acquisition of such property or assets or the acquisition of the Capital Stock of any Person owning such property or assets, in an aggregate outstanding principal amount as of the date of any incurrence pursuant to this clause (4) which, when taken together with the principal amount of all other Indebtedness incurred pursuant to this clause (4) and that is then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (4) and then outstanding), will not exceed the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

(5) (i) Indebtedness of the Issuer owing to any of its Restricted Subsidiaries or Indebtedness of any of its Restricted Subsidiaries owing to the Issuer or any other Restricted Subsidiary of the Issuer; provided that any such Indebtedness of the Issuer or a Guarantor owing to a Restricted Subsidiary that is not a Guarantor shall be subordinated in right of payment to the Notes; and provided further, (A) any subsequent issuance or transfer of Equity Interests that results in any such Indebtedness being held by a Person other than the Issuer or a Restricted Subsidiary and (B) any transfer of such Indebtedness to a Person that is not the Issuer or a Restricted Subsidiary will be deemed, in each case, to constitute an incurrence of such Indebtedness by the Issuer or such Restricted Subsidiary, as the case may be, that was not permitted by this clause (5); and (ii) in connection with any Indebtedness permitted by subclause (i), any such Indebtedness that is secured by a Lien on any assets or property that is required to be pledged as collateral in order to obtain or maintain any Non-Recourse Financing shall be permitted and such Indebtedness and Lien may be assigned or transferred to third party lenders providing such Non-Recourse Financing;

(6) the issuance by any of the Issuer’s Restricted Subsidiaries to the Issuer or to any of its Restricted Subsidiaries of shares of Preferred Equity; provided, however, that (A) any subsequent issuance or transfer of Equity Interests that results in any such Preferred Equity being held by a Person other than the Issuer or a Restricted Subsidiary of the Issuer, and (B) any sale or other transfer of any such Preferred Equity to a Person that is not either the Issuer or a Restricted Subsidiary of the Issuer, will be deemed, in each case, to constitute an issuance of such Preferred Equity by such Restricted Subsidiary that was not permitted by this clause (6);

(7) (x) Indebtedness or Disqualified Stock incurred or issued by the Issuer or a Restricted Subsidiary to finance an acquisition or Investment or (y) Indebtedness, Disqualified Stock or Preferred Equity of a Restricted Subsidiary incurred and outstanding on the date on which such Restricted Subsidiary was directly or indirectly acquired by the Issuer or a Restricted Subsidiary after the Issue Date or on the date it otherwise becomes a Restricted Subsidiary; provided that if, in the case of clause (x), such Indebtedness, Disqualified Stock is incurred or issued by a Recourse Person or is otherwise recourse to a

 

94


Recourse Person, or in the case of clause (y), such Restricted Subsidiary is a Recourse Person or such Indebtedness, Disqualified Stock or Preferred Equity is otherwise recourse to a Recourse Person, then in each such case after giving pro forma effect to such incurrence, issuance or acquisition, as applicable, either (A) the Issuer would be permitted to incur at least $1.00 of additional Indebtedness pursuant to the Holdco Debt Ratio test set forth in Section 4.09(a) or (B) the Holdco Debt Ratio for the applicable Test Period would be equal to or less than immediately prior to such acquisition and incurrence; and provided further, that Indebtedness, Disqualified Stock or Preferred Equity incurred or issued under this clause (7) in contemplation of such transaction will only be permitted if (i) such Restricted Subsidiary becomes a Guarantor to the extent required to do so pursuant to Section 4.16 or (ii) such Restricted Subsidiary is a Non-Recourse Subsidiary;

(8) Indebtedness of the Issuer and its Restricted Subsidiaries incurred in respect of worker’s compensation claims or claims arising under similar legislation, self-insurance or similar obligations, performance, surety and similar bonds and performance and completion guarantees provided by the Issuer and its Restricted Subsidiaries in the ordinary course of business, or consistent with past practice or industry norms (including, for the avoidance of doubt, incurred in connection with the development, financing (including refinancing), engineering, procurement, construction, commissioning, completion, operation, maintenance or insuring of any Project by any Subsidiary or any related activities to the extent incurred prior to the date of any Non-Recourse Financing by such Project);

(9) Indebtedness, Disqualified Stock and Preferred Stock of the Issuer and its Restricted Subsidiaries providing for indemnification, payment obligations in respect of any non-compete, consulting or similar arrangement, adjustment of purchase price, deferred purchase price (including adjustments thereof, contingent obligations, earn-outs and similar obligations) or progress payments for property or services, or other similar adjustments or obligations in connection with the acquisition or disposition of any business, assets or Capital Stock of a Subsidiary of the Issuer after the Issue Date;

(10) Indebtedness consisting of cash management obligations, netting services, overdraft protection and similar arrangements incurred in the ordinary course of business;

(11) (i) advance payments received from customers for goods and services purchased and credit periods in the ordinary course of business, and (ii) trade or other similar Indebtedness incurred in the ordinary course of business, which is (x) not more than ninety (90) days past due or (y) being contested in good faith and by appropriate proceedings;

(12) Indebtedness constituting reimbursement obligations with respect to letters of credit, bankers’ acceptances, discounted bills of exchange or the discounting or factoring of receivables or payables for credit management purposes, or similar instruments or obligations, in each case incurred or issued in the ordinary course of business or consistent with past practice or industry norms;

 

95


(13) Indebtedness in respect of (i) cash pooling arrangements, (ii) Bank Product Obligations and (iii) Hedging Obligations (other than Hedging Obligations incurred for speculative purposes);

(14) the guarantee by (i) the Issuer or a Restricted Subsidiary of Indebtedness (other than any Non-Recourse Financing) that is permitted to be incurred pursuant to another provision of this Section 4.09; provided that if the Indebtedness being guaranteed is subordinated to or pari passu with the Notes, then the guarantee will be subordinated or pari passu, as applicable, to the same extent as the Indebtedness guaranteed; and (ii) any Non-Recourse Subsidiary of Indebtedness of any other Non-Recourse Subsidiary to the extent such Indebtedness constitutes a Non-Recourse Financing after giving effect to such guarantee;

(15) Indebtedness in connection with any Permitted Receivables Financing;

(16) Indebtedness that constitutes Non-Recourse Financing that is incurred by a Non-Recourse Subsidiary and any Disqualified Stock and Preferred Equity issued by a Non-Recourse Subsidiary (including Disqualified Stock and Preferred Equity outstanding at the time such Non-Recourse Subsidiary becomes a Restricted Subsidiary);

(17) the guarantee by, or any other credit support from, a Recourse Person of any Non-Recourse Financing; provided that the aggregate principal amount of all Indebtedness incurred under this clause (17) and then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (17) and then outstanding) does not exceed the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

(18) Indebtedness of the Issuer or its Restricted Subsidiaries incurred pursuant to an ECR Transaction;

(19) guarantees by the Issuer or its Restricted Subsidiaries in the ordinary course of business of obligations to suppliers, customers, franchisees and licensees;

(20) Indebtedness representing deferred compensation to employees of the Issuer or any of its Restricted Subsidiaries;

(21) Indebtedness consisting of the financing of insurance premiums or take-or-pay obligations contained in supply agreements, in each case, in the ordinary course of business;

(22) Indebtedness, Disqualified Stock or Preferred Equity of the Issuer or any of its Restricted Subsidiaries in an aggregate outstanding principal amount as of the date of any incurrence pursuant to this clause (22) which, when taken together with the principal amount of all other Indebtedness incurred pursuant to this clause (22) and then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (22) that is then outstanding), will not exceed the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

 

96


(23) the guarantee by, or any other credit support from, the Issuer or any of its Restricted Subsidiaries of Indebtedness of any Unrestricted Subsidiary or any Joint Venture; provided that the aggregate principal amount of all Indebtedness incurred by any Recourse Person under this clause (23) and then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (w) and then outstanding) does not exceed the greater of (A) $500 million and (B) 15.0% of Distributable Cash for the applicable Test Period;

(24) any Refinancing Indebtedness incurred with respect to the refinancing of any Indebtedness permitted under Section 4.09(a) or clauses (1), (2), (3), (4), (7), (17), (22), (23), this (24), (25) or (30) of this Section 4.09(b);

(25) Indebtedness, Disqualified Stock and Preferred Stock represented by Management Advances;

(26) Indebtedness, Disqualified Stock or Preferred Equity of the Issuer or any Restricted Subsidiary in an aggregate principal amount or liquidation preference at any time outstanding, together with Refinancing Indebtedness in respect thereof incurred or issued pursuant to clause (x) above, not greater than 100.0% of the net cash proceeds received by the Issuer and the Restricted Subsidiaries since immediately after the Reference Date from the issue or sale of Equity Interests of the Issuer or any Parent Entity (which proceeds are contributed to the Issuer or a Restricted Subsidiary) or cash contributed to the capital of the Issuer (in each case other than proceeds of Disqualified Stock or sales of Equity Interests to, or contributions received from, the Issuer or any of its Subsidiaries) to the extent such net cash proceeds or cash have not been applied to make Restricted Payments or to make other Investments, payments or exchanges pursuant to Section 4.07(b) or to make Permitted Investments (other than Permitted Investments specified in clauses (1) and (2) of the definition thereof) and are not included in Incremental Funds;

(27) any Indebtedness representing Project Obligations or Permitted Project Undertakings;

(28) Indebtedness, Disqualified Stock and Preferred Stock incurred by the Issuer or any of its Restricted Subsidiaries to the extent that the net proceeds thereof are promptly deposited with the Trustee to satisfy or discharge the Notes or exercise the Issuer’s legal defeasance or covenant defeasance, in each case, in accordance with this Indenture;

(29) Indebtedness, Disqualified Stock and Preferred Stock arising from Permitted Intercompany Activities; and

(30) Indebtedness of the Issuer or any Guarantor that is unsecured and is expressly subordinated in right of payment to the Notes; provided that the aggregate principal amount of all such Indebtedness incurred pursuant to this clause (30) and that is then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (30) and then outstanding) shall not exceed the greater of (A) $1.0 billion and (B) 30.0% of Distributable Cash for the applicable Test Period.

 

97


For purposes of this Indenture, no Indebtedness will be deemed to be contractually subordinated in right of payment to any other Indebtedness of the Issuer or the Guarantors solely by virtue of being unsecured or by virtue of being secured on a junior priority basis.

For purposes of determining compliance with this Section 4.09, in the event that an item of proposed Indebtedness meets the criteria of more than one of the categories described in paragraphs (b)(1) through (30) of this Section 4.09, or is entitled to be incurred in whole or in part pursuant to paragraph (a) of this Section 4.09, the Issuer will be permitted to divide and classify such item of Indebtedness on the date of its incurrence and later divide and reclassify all or a portion of such item of Indebtedness, in any manner that complies with this Section 4.09; for the avoidance of doubt, any incurrence of Indebtedness may, if applicable, be classified in part as being incurred and outstanding under the first paragraph of this covenant and in part as being incurred and outstanding under one or more categories of Permitted Debt.

(c) For purposes of determining compliance with this Section 4.09, (1) guarantees of, or obligations in respect of letters of credit, bankers’ acceptances or other similar instruments relating to, or Liens securing, Indebtedness, Disqualified Stock or Preferred Stock that is otherwise included in the determination of a particular amount of Indebtedness, Disqualified Stock or Preferred Stock shall not be included, and (2) if obligations in respect of letters of credit, bankers’ acceptances or other similar instruments are incurred pursuant to any Credit Facility and are being treated as incurred pursuant to any clause of Section 4.09(b) or Section 4.09(a) and the letters of credit, bankers’ acceptances or other similar instruments relate to other Indebtedness, Disqualified Stock or Preferred Stock, then such other Indebtedness, Disqualified Stock or Preferred Stock shall not be included.

The accrual of interest or Preferred Equity dividends, the accretion or amortization of original issue discount, the payment of interest on any Indebtedness in the form of additional Indebtedness with the same terms, the reclassification of Preferred Equity as Indebtedness due to a change in accounting principles, and the payment of dividends on Preferred Equity or Disqualified Stock in the form of additional shares of the same class of Preferred Equity or Disqualified Stock will not be deemed to be an incurrence of Indebtedness or an issuance of Preferred Equity or Disqualified Stock for purposes of this Section 4.09. For purposes of determining compliance with any U.S. dollar-denominated restriction on the incurrence of Indebtedness, the U.S. dollar-equivalent principal amount of Indebtedness denominated in a foreign currency shall be utilized, calculated based on the relevant currency exchange rate in effect on the date such Indebtedness was incurred. Notwithstanding any other provision of this Section 4.09, the maximum amount of Indebtedness that the Issuer or any Restricted Subsidiary may incur pursuant to this Section 4.09 shall not be deemed to be exceeded solely as a result of fluctuations in exchange rates or currency values. In the case of any Refinancing Indebtedness, when measuring the outstanding amount of such Indebtedness, such amount shall not include the aggregate amount of accrued and unpaid interest, dividends, premiums (including tender premiums), defeasance costs, underwriting discounts, fees, costs and expenses (including original issue discount, upfront fees or similar fees) in connection with such refinancing.

 

98


The amount of any Indebtedness outstanding as of any date will be:

(1) the accreted value of the Indebtedness, in the case of any Indebtedness issued with original issue discount;

(2) the principal amount of the Indebtedness, in the case of any other Indebtedness; and

(3) in respect of Indebtedness of another Person secured by a Lien on the assets of the specified Person, the lesser of:

(A) the Fair Market Value of such assets at the date of determination; and

(B) the amount of the Indebtedness of the other Person.

Section 4.10 Limitation on Sales of Assets.

(a) The Issuer will not, and will not permit any of its Restricted Subsidiaries to, directly or indirectly, consummate an Asset Sale unless:

(1) the Issuer (or the relevant Restricted Subsidiary, as the case may be) receives consideration at the time of the Asset Sale at least equal to the Fair Market Value of the assets or Equity Interests issued or sold or otherwise disposed of (as determined in good faith by the Issuer at the time of contractually agreeing to such Asset Sale);

(2) at least 75% of the consideration received in the Asset Sale, calculated on a cumulative basis, by the Issuer or such Restricted Subsidiary is in the form of cash or Cash Equivalents. For purposes of this provision, each of the following will be deemed to be cash:

(A) any liabilities, as recorded on the balance sheet of the Issuer or any Restricted Subsidiary (contingent or otherwise), that are assumed or discharged by the transferee (or a third party in connection with such transfer) of any such assets and as a result of which the Issuer and its Restricted Subsidiaries are no longer obliged with respect to such liabilities or are indemnified against further liabilities;

(B) any securities, notes or other obligations received by the Issuer or any such Restricted Subsidiary from such transferee that are converted by the Issuer or such Restricted Subsidiary into cash or Cash Equivalents within 180 days following the closing of the Asset Sale, to the extent of the cash or Cash Equivalents received in that conversion;

(C) any Capital Stock of any Person that will become on the date of acquisition thereof a Restricted Subsidiary as a result of such acquisition and that is involved principally in Permitted Businesses or properties and assets (other than cash or any Capital Stock or other security) that will be used in a Permitted Business of the Issuer and its Restricted Subsidiaries;

 

99


(D) Indebtedness of any Restricted Subsidiary that is no longer a Restricted Subsidiary as a result of such Asset Sale, to the extent that the Issuer and each other Restricted Subsidiary are released from any guarantee of such Indebtedness in connection with such Asset Sale;

(E) consideration consisting of Indebtedness of the Issuer or any Guarantor received from persons who are not the Issuer or any Restricted Subsidiary;

(F) any consideration consisting of Equity Interests in an entity (including a Non-Recourse Subsidiary) engaged in a Permitted Business received in connection with the sale or exchange of an Equity Interest in a Restricted Subsidiary so long as after giving effect to such transaction, the entity in which the Equity Interests have been sold or exchanged remains a Restricted Subsidiary, provided that if such Equity Interests sold or exchanged constituted Collateral the Equity Interests received as consideration constitute Collateral subsequent to such sale or exchange; and

(G) any Designated Non-cash Consideration received by the Issuer or such Restricted Subsidiary in such Asset Sale having an aggregate Fair Market Value, taken together with all other Designated Non-cash Consideration received since the Issue Date pursuant to this clause (G) that is at that time outstanding, not to exceed the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period, determined at the time of receipt of such Designated Non-cash Consideration (with the Fair Market Value of each item of Designated Non-cash Consideration being determined as of the date of receipt thereof and without giving effect to subsequent changes in value).

(b) Within 450 days after the receipt of any Net Proceeds from an Asset Sale, the Issuer (or the applicable Restricted Subsidiary, as the case may be) may:

(1) apply an amount of cash up to the Asset Sale Prepayment Percentage of such Net Proceeds (at the option of the Issuer or Restricted Subsidiary):

(A) to redeem Notes on a ratable basis as described in Section 3.07, to purchase Notes on a ratable basis through open market purchases (to the extent such purchases are at or above 100% of the principal amount thereof) or to purchase Notes pursuant to an offer to all Holders at a purchase price equal to at least 100% of the principal amount thereof, plus accrued and unpaid interest, if any, to (but not including) the date of purchase in accordance with Article 3 (a “Notes Offer”), which Notes Offer will constitute an application of the Asset Sale Prepayment Percentage of such Net Proceeds pursuant to this clause to the extent of the amount of the Notes Offer, whether or not any Notes are tendered;

 

100


(B) to the extent such Net Proceeds are from an Asset Sale of Collateral or other assets of a Recourse Person, to repurchase, prepay, redeem or repay: (i) Indebtedness of a Recourse Person that is not the Issuer or a Guarantor (other than Indebtedness owed to the Issuer or a Restricted Subsidiary), or (ii) First Lien Obligations (other than the Notes), and in the case of revolving obligations, to correspondingly reduce commitments with respect thereto; provided that in the case of clause (ii), a pro rata portion of such amount of cash is applied to redeem Notes on a ratable basis as described in Section 3.07 purchase Notes on a ratable basis through open market purchases (to the extent such purchases are at or above 100% of the principal amount thereof) or to make a Notes Offer, which Notes Offer will constitute an application of such amount of cash pursuant to this clause to the extent of the amount of the Notes Offer, whether or not any Notes are tendered;

(C) to the extent such Net Proceeds are from an Asset Sale that does not constitute Collateral or other assets of a Recourse Person: (i) to make an Investment in, or to acquire all or substantially all of the assets of, or any Capital Stock of, any Permitted Business, if, after giving effect to any such acquisition of Capital Stock, the Permitted Business is or becomes a Restricted Subsidiary (including a Non- Recourse Subsidiary), (ii) to make capital expenditures, (iii) to acquire other assets (other than Capital Stock) that are used or useful in any Project or Permitted Business, (iv) to reduce, prepay, repay or purchase any Indebtedness secured by a Lien on such asset (and terminate the related commitments if such Indebtedness is revolving Indebtedness), (v) to repurchase, prepay, redeem or repay Indebtedness of a Restricted Subsidiary that is not a Guarantor (other than Indebtedness owed to the Issuer or another Restricted Subsidiary), (vi) to repurchase, prepay, redeem or repay Senior Indebtedness (other than the Notes); provided that, in the case of this clause (vi) a pro rata portion of such amount of cash is applied to redeem Notes on a ratable basis as described under Section 3.07, purchase Notes on a ratable basis through open market purchases (to the extent such purchases are at or above 100% of the principal amount thereof) or to make a Notes Offer, which Notes Offer will constitute an application of such amount of cash pursuant to this clause to the extent of the amount of the Notes Offer, whether or not any Notes are tendered, or (vii) to repurchase, prepay, redeem or repay any Non-Recourse Financing or Indebtedness incurred pursuant to any ECR Transaction; or

(D) any combination of the foregoing; or

(2) enter into a binding commitment to apply the Asset Sale Prepayment Percentage of such Net Proceeds pursuant to clauses (1)(C)(i), (ii) or (iii) of this Section 4.10(b); provided that such binding commitment will be treated as a permitted application of the Asset Sale Prepayment Percentage of such Net Proceeds from the date of such commitment until the earlier of: (x) the date on which such acquisition or expenditure is consummated; and (y) the 180th day following the expiration of the aforementioned 450-day period.

Pending the final application of any Asset Sale Prepayment Percentage of such Net Proceeds, the Issuer (or any applicable Restricted Subsidiary) may temporarily reduce Indebtedness (including under any Credit Facility) or otherwise invest the Asset Sale Prepayment Percentage of such Net Proceeds in any manner that is not prohibited by this Indenture.

 

101


(c) Any Net Proceeds from Asset Sales (other than Retained Asset Sale Proceeds) of Collateral that are not applied or invested as provided in Section 4.10(b) hereof will constitute “Collateral Excess Proceeds.” When the aggregate amount of Collateral Excess Proceeds exceeds the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period, within ten Business Days thereof, the Issuer will make an offer (a “Collateral Asset Sale Offer”) to all Holders on a pro rata basis and may make an offer to all holders of other First Lien Obligations to purchase, prepay or redeem the maximum principal amount of Notes on a pro rata basis and such other First Lien Obligations (plus all accrued interest on the Indebtedness and the amount of all fees and expenses, including premiums, incurred in connection therewith) that may be purchased, prepaid or redeemed out of the Collateral Excess Proceeds. The offer price for the Notes in any Collateral Asset Sale Offer will be equal to 100% of the principal amount, plus accrued and unpaid interest to the date of purchase, prepayment or redemption, subject to the rights of Holders on the relevant record date to receive interest due on the relevant Interest Payment Date, and will be payable in cash. If any Collateral Excess Proceeds remain after consummation of a Collateral Asset Sale Offer (“Declined Collateral Excess Proceeds”), the Issuer may use those Declined Collateral Excess Proceeds for any purpose not otherwise prohibited by this Indenture. If the aggregate principal amount of Notes and other Additional First Lien Obligations tendered into (or to be prepaid or redeemed in connection with) such Collateral Asset Sale Offer exceeds the amount of Collateral Excess Proceeds or if the aggregate amount of the Notes tendered pursuant to a Notes Offer exceeds the amount of the Net Proceeds so applied, such Notes and such other First Lien Obligations, if applicable, will be purchased on a pro rata basis, based on the amounts tendered or required to be prepaid or redeemed (with such adjustments as may be deemed appropriate by the Issuer so that only Notes in denominations of $2,000, or an integral multiple of $1,000 in excess thereof, will be purchased). Upon completion of each Collateral Asset Sale Offer, the amount of Collateral Excess Proceeds will be reset at zero. The Issuer may satisfy the foregoing obligations with respect to any Net Proceeds from an Asset Sale by making a Collateral Asset Sale Offer with respect to such Net Proceeds prior to the time period that may be required by this Indenture with respect to all or a part of the available Net Proceeds (the “Collateral Advance Portion”) in advance of being required to do so by this Indenture (a “Collateral Advance Offer”).

(d) Any Net Proceeds from Asset Sales (other than Retained Asset Sale Proceeds) that do not constitute Collateral that are not applied or invested as provided in Section 4.10(b) hereof will constitute “Excess Proceeds.” When the aggregate amount of Excess Proceeds exceeds the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period, within ten Business Days thereof, the Issuer will make an offer (an “Asset Sale Offer”) to all Holders on a pro rata basis and may make an offer to all holders of other Senior Indebtedness to purchase, prepay or redeem the maximum principal amount of Notes on a pro rata basis and such other Senior Indebtedness (plus all accrued interest on the Indebtedness and the amount of all fees and expenses, including premiums, incurred in connection therewith) that may be purchased, prepaid or redeemed out of the Excess Proceeds. The offer price for the Notes in any Asset Sale Offer will be equal to 100% of the principal amount, plus accrued and unpaid interest to the date of purchase, prepayment or redemption, subject to the rights of Holders on the relevant record date to receive interest due on the relevant Interest Payment Date, and will be payable in cash. If any Excess Proceeds remain after consummation of an Asset Sale Offer (“Declined Non-Collateral Excess Proceeds” and, together with the Declined Collateral Excess Proceeds, “Declined Excess Proceeds”), the Issuer may use those Declined Non-Collateral Excess Proceeds for any purpose not otherwise prohibited by this Indenture. If the aggregate principal amount of Notes and other

 

102


Senior Indebtedness tendered into (or to be prepaid or redeemed in connection with) such Asset Sale Offer exceeds the amount of Excess Proceeds or if the aggregate amount of the Notes tendered pursuant to a Notes Offer exceeds the amount of the Net Proceeds so applied, such Notes and such other Senior Indebtedness, if applicable, will be purchased on a pro rata basis, based on the amounts tendered or required to be prepaid or redeemed (with such adjustments as may be deemed appropriate by the Issuer so that only Notes in denominations of $2,000, or an integral multiple of $1,000 in excess thereof, will be purchased). Upon completion of each Asset Sale Offer, the amount of Excess Proceeds will be reset at zero. The Issuer may satisfy the foregoing obligations with respect to any Net Proceeds from an Asset Sale by making an Asset Sale Offer with respect to such Net Proceeds prior to the time period that may be required by this Indenture with respect to all or a part of the available Net Proceeds (the “Advance Portion”) in advance of being required to do so by this Indenture (a “Advance Offer”).

(e) The Issuer will comply with the requirements of Rule 14e-1 under the Exchange Act and any other securities laws and regulations thereunder to the extent those laws and regulations are applicable in connection with each repurchase of Notes pursuant to an Asset Sale Offer. To the extent that the provisions of any securities laws or regulations conflict with the provisions of Section 3.09 hereof or this Section 4.10, the Issuer will comply with the applicable securities laws and regulations and will not be deemed to have breached its obligations under Section 3.09 hereof or this Section 4.10 by virtue of such compliance.

(f) The provisions of Section 3.09 and this Section 4.10 may be waived or modified with the written consent of the Holders of a majority in aggregate principal amount of all the then outstanding Notes.

Section 4.11 Limitation on Transactions with Affiliates.

(a) The Issuer will not, and will not permit any Restricted Subsidiary to, directly or indirectly, enter into any transaction or series of related transactions (including, without limitation, the sale, purchase, exchange or lease of assets or property or the rendering of any service) with, or for the benefit of, any Affiliate of the Issuer or any Restricted Subsidiary involving aggregate payments or consideration in excess of the greater of (A) $75 million and (B) 2.0% of Distributable Cash for the applicable Test Period (each, an “Affiliate Transaction”), unless:

(1) such transaction or series of transactions is on terms that, taken as a whole, are not materially less favorable to the Issuer or such Restricted Subsidiary, as the case may be, than those that would have been obtained in a comparable transaction at such time on an arm’s-length basis with third parties that are not Affiliates, or, if in the good faith judgment of the Issuer, no comparable transaction is available with which to compare such Affiliate Transaction, such Affiliate Transaction is otherwise fair to the Issuer or such Restricted Subsidiary from a financial point of view and when such transaction is taken in its entirety; and

(2) with respect to any transaction or series of related transactions involving aggregate payments or the transfer of assets or the provision of services, in each case having a value that exceeds the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period, the Issuer’s Board of Directors must approve such transaction (including a majority of the disinterested directors).

 

103


(b) Notwithstanding the foregoing, the restrictions set forth in Section 4.11(a) will not apply to:

(1) customary directors’ fees and expenses, indemnities and similar arrangements (including the payment of directors’ and officers’ insurance premiums), consulting fees, employee compensation, employee and director bonuses, employment agreements and arrangements or employee benefit arrangements, including stock options or legal fees, as determined in good faith by the Issuer;

(2) Permitted Investments and Restricted Payments that are permitted by Section 4.07 (including any transaction that would otherwise constitute a Restricted Payment but is expressly excluded from the definition of the term “Restricted Payments”);

(3) any Management Advances and any waiver or transaction with respect thereto;

(4) agreements and arrangements existing on the Issue Date, and the performance by the Issuer or any Restricted Subsidiary of their obligations thereunder and any amendments, modifications, replacements or supplements thereto or similar agreements entered into in the future; provided that any such amendments, modifications, replacements or supplements, taken as a whole, or any such similar agreements, are not more disadvantageous to the Holders in any material respect than the original agreements or arrangements as in effect on the Issue Date (as determined by the Issuer in good faith) or as are not otherwise prohibited by this Section 4.11;

(5) the issuance of securities pursuant to, or for the purpose of the funding of, employment, termination or severance arrangements, stock options and stock ownership plans, as long as the terms thereof are or have been previously approved by the Issuer’s or the relevant Restricted Subsidiary’s Board of Directors;

(6) (i) transactions between or among, or for the benefit of, the Issuer and the Restricted Subsidiaries (or entity that becomes a Restricted Subsidiary as a result of such transaction), or between or among Restricted Subsidiaries, and (ii) any merger, amalgamation or consolidation with any Parent Entity, provided that, in the case of this clause (ii), such Parent Entity shall have no material liabilities and no material assets other than cash, Cash Equivalents and the Capital Stock of the Issuer and such merger, amalgamation or consolidation is otherwise not prohibited under this Indenture;

(7) payments to or from, and transactions with, customers, clients, suppliers or purchasers or sellers of goods or services, or transactions otherwise relating to the purchase or sale of goods or services (including any cash management activities related thereto), in each case in the ordinary course of business or consistent with past practice or industry norms, or that are on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable as might reasonably have been obtained at such time from an unaffiliated party, in each case as determined by the Issuer in good faith;

 

104


(8) any issuance of Equity Interests (other than Disqualified Stock) of the Issuer;

(9) the pledge of Equity Interests of Unrestricted Subsidiaries;

(10) any contribution to the capital of the Issuer;

(11) transactions with respect to which the Issuer has obtained an opinion as to the fairness to the Issuer and its Restricted Subsidiaries from a financial point of view issued by an accounting, appraisal or investment banking firm of national standing;

(12) transactions permitted by, and complying with, the provisions of, Article 5;

(13) transactions with (i) Unrestricted Subsidiaries or (ii) Joint Ventures in which the Issuer or a Subsidiary of the Issuer holds or acquires an ownership interest (whether by way of Capital Stock or otherwise) or any partners of any such Joint Venture, in each case entered into in the ordinary course or business or consistent with past practice or industry norms (including, without limitation, any cash management activities related thereto), or that are on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable to the Issuer or the applicable Restricted Subsidiary as might reasonably have been obtained at such time from an unaffiliated party (as determined by the Issuer in good faith);

(14) transactions between the Issuer or any of its Restricted Subsidiaries and any Person that is an Affiliate solely as a result of the ownership by the Issuer or any of the Restricted Subsidiaries of Capital Stock of such Person;

(15) transactions with Persons solely in their capacity as holders of Indebtedness of the Issuer or any of its Restricted Subsidiaries where such Persons are treated no more favorably than holders of Indebtedness of the Issuer or such Restricted Subsidiaries generally;

(16) transactions entered into by (i) an Unrestricted Subsidiary with an Affiliate prior to the time such Unrestricted Subsidiary becomes a Restricted Subsidiary or (ii) a Person acquired by or merged, amalgamated, or consolidated with or into the Issuer or any Restricted Subsidiary prior to the time of such acquisition, merger, amalgamation or consolidation, as applicable;

(17) (i) investments by Affiliates in securities or loans or other Indebtedness of the Issuer or any of its Restricted Subsidiaries (and payment of out-of-pocket expenses incurred by such Affiliates in connection therewith) so long as the investment is being offered by the Issuer or such Restricted Subsidiary generally to other investors on the same or more favorable terms, and (ii) payments to Affiliates in respect of securities or loans or other Indebtedness of the Issuer or any of its Restricted Subsidiaries contemplated in the foregoing subclause (i) or that were acquired from Persons other than the Issuer and its Restricted Subsidiaries, in each case, in accordance with the terms of such securities or loans;

 

105


(18) transfers of leases, servitudes or similar assets and the entry into related license agreements, in each case, in the ordinary course of business or consistent with past practice or industry norms;

(19) any lease entered into between the Issuer or any Restricted Subsidiary, as lessee, and any Affiliate of the Issuer, as lessor, in each case entered into in the ordinary course of business or consistent with past practice or industry norms, or that is on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable as might reasonably have been obtained at such time from an unaffiliated party, in each case as determined by the Issuer in good faith;

(20) any administrative services agreement, operations and maintenance agreement, marketing agreement, charter agreement, shipping agency agreement, reciprocal services agreement, excess capacity offtake agreement (including any sale and purchase agreement entered into in connection therewith) or other similar agreement or arrangement with the VGP Investor or any of its Affiliates relating to, or otherwise entered into in connection with, any Project or Permitted Business, in each case entered into in the ordinary course or business or consistent with past practice or industry norms, or that are on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable to the Issuer or the applicable Restricted Subsidiary as might reasonably have been obtained at such time from an unaffiliated party, in each case as determined by the Issuer in good faith;

(21) payments by the Issuer or any Restricted Subsidiary (including any payment to any Parent Entity for further payment by such Parent Entity), (A) to reimburse the VGP Investor and any of its Affiliates and designees for any reasonable or customary out-of-pocket costs and expenses incurred in connection with the provision of any management, advisory, consulting or other similar services, and (B) to pay reasonable or customary management, monitoring, consulting and similar fees to the VGP Investor; provided that, in the case of the foregoing subclause (B), no such payments shall be made if an Event of Default shall have occurred and be continuing or would immediately result after giving pro forma effect to such payments (it being agreed that such amounts may accrue, but not be payable in cash during such period; provided that all such accrued amounts (plus accrued interest, if any, with respect thereto) may be payable in cash upon the cure or waiver of such Event of Default);

(22) the existence of, or the performance by the Issuer or any of its Restricted Subsidiaries of its obligations under the terms of, any stockholders agreement (including any registration rights agreement or purchase agreement relating thereto) in effect as of the Issue Date and any amendments, modifications, replacements or supplements thereto or similar agreements entered into in the future; provided that any such amendments, modifications, replacements or supplements, taken as a whole, or any such similar agreements, are not more disadvantageous to the holders of the Notes in any material respect than the original agreements or arrangements as in effect on the Issue Date (as determined by the Issuer in good faith) or as are not otherwise prohibited by this Section 4.11;

 

106


(23) any transactions with any Captive Insurance Subsidiary;

(24) any Project Obligations, Permitted Project Undertakings and ECR Transactions;

(25) any Permitted Intercompany Activities, any IPO Reorganization Transactions, any Tax Restructuring, and related transactions; and

(26) sales of accounts receivable, or participations therein, or accounts receivable, royalty or other revenue streams and other rights to payment and any other assets, or other transactions, in connection with any Permitted Receivables Financing.

Section 4.12 Limitation on Liens.

(a) The Issuer will not, and will not permit any of its Restricted Subsidiaries to create, any Lien upon the whole or any part of the currently owned or after-acquired property of the Issuer or any of its Restricted Subsidiaries or assets (each, a “Subject Lien”) to secure any Indebtedness or any guarantee or indemnity in respect of any Indebtedness (other than Permitted Liens), unless, in the case of any Subject Lien on any asset or property that is not Collateral, the Notes (or a Guarantee in the case of Subject Liens on assets or property of a Guarantor) are equally and ratably secured with (or on a senior basis to, in the case such Subject Lien secures any Subordinated Indebtedness) the Obligations secured by such Subject Lien until such time as such Obligations are no longer secured by such Subject Lien.

(b) Any Lien created for the benefit of the holders of the Notes pursuant to this Section 4.12 shall be deemed automatically and unconditionally released and discharged upon the release and discharge of the Subject Lien that gave rise to the obligation to secure the Notes. In addition, in the event that a Subject Lien is or becomes a Permitted Lien, the Issuer may, at its option and without consent from any holder of the Notes, elect to release and discharge any Lien created for the benefit of the holders pursuant to Section 4.12(a) in respect of such Subject Lien.

(c) With respect to any Lien securing Indebtedness that was permitted to secure such Indebtedness at the time of the Incurrence of such Indebtedness, such Lien shall also be permitted to secure any Increased Amount of such Indebtedness. The “Increased Amount” of any Indebtedness shall mean any increase in the amount of such Indebtedness in connection with any accrual of interest, the accretion of accreted value, the amortization of original issue discount, the payment of interest in the form of additional Indebtedness with the same terms, accretion of original issue discount or liquidation preference and increases in the amount of Indebtedness outstanding solely as a result of fluctuations in the exchange rate of currencies or increases in the value of property securing Indebtedness.

Section 4.13 [Reserved].

 

107


Section 4.14 Corporate Existence.

Subject to Article 5 hereof, the Issuer shall do or cause to be done all things necessary to preserve and keep in full force and effect its existence, and the corporate, partnership, limited liability company or other existence of each of its Restricted Subsidiaries, in accordance with the respective organizational documents (as the same may be amended from time to time) of the Issuer or any such Restricted Subsidiary; provided that the Issuer shall not be required to preserve the corporate, partnership or other existence of its Restricted Subsidiaries, if the Issuer in good faith shall determine that the preservation thereof is no longer desirable in the conduct of the business of the Issuer and its Restricted Subsidiaries, taken as a whole. For the avoidance of doubt, the Issuer and its Restricted Subsidiaries will be permitted to change their organizational form.

Section 4.15 Offer to Repurchase Upon Change of Control Triggering Event.

(a) Upon the occurrence of a Change of Control Triggering Event with respect to any series of Notes, the Issuer will be required to make an offer (a “Change of Control Offer”) to each Holder of Notes of such series to repurchase all or any part (being not less than $2,000 or an integral multiple of $1,000 in excess thereof) of that Holder’s Notes of such series pursuant to the terms set forth in this Section 4.15.

(b) In the Change of Control Offer, the Issuer will offer a payment in cash (the “Change of Control Payment”) equal to 101% of the aggregate principal amount of Notes of the applicable series repurchased, plus accrued and unpaid interest, if any, on the Notes repurchased to, but not including, the date of purchase (the “Change of Control Payment Date”), subject to the rights of Holders on the relevant record date to receive interest, if any, due on the relevant Interest Payment Date. Within 30 days following any Change of Control Triggering Event, the Issuer will mail, or deliver electronically if the Notes of the applicable series are held at DTC, a notice to each Holder describing the transaction or transactions that constitute the Change of Control Triggering Event and offering to repurchase such Notes on the Change of Control Payment Date specified in the notice, which date will be no earlier than 30 days and no later than 60 days from the date such notice is mailed or electronically delivered, pursuant to the procedures required by this Indenture and described in such notice, except in the case of a conditional Change of Control Offer made in advance of a Change of Control as described below. The Issuer will comply with the requirements of Rule 14e-1 under the Exchange Act and any other securities laws and regulations thereunder to the extent those laws and regulations are applicable in connection with the repurchase of the Notes of the applicable series as a result of a Change of Control Triggering Event. To the extent that the provisions of any securities laws or regulations conflict with this Section 4.15, the Issuer will comply with the applicable securities laws and regulations and will not be deemed to have breached its obligations in this Section 4.15 by virtue of such compliance. The Issuer may rely on any no-action letters issued by the Commission indicating that the staff of the Commission will not recommend enforcement action in the event a tender offer satisfies certain conditions.

(c) On the Change of Control Payment Date, the Issuer will, to the extent lawful:

(1) accept for payment all Notes or portions of Notes properly tendered pursuant to the Change of Control Offer;

(2) deposit with the Paying Agent an amount equal to the Change of Control Payment in respect of all Notes or portions of Notes properly tendered; and

 

108


(3) deliver or cause to be delivered to the Trustee the Notes properly accepted together with an Officer’s Certificate stating the aggregate principal amount of Notes or portions of Notes being purchased by the Issuer.

The Paying Agent will promptly deliver to each Holder of Notes properly tendered the Change of Control Payment for such Notes(or, if all the Notes are then in global form, make such payment through the facilities of DTC), and, for any Notes represented by certificated notes, the Trustee will, upon receipt of an Authentication Order, promptly authenticate and mail (or cause to be transferred by book entry) to such Holder a new certificated note representing equal in principal amount to any unpurchased portion of the Notes surrendered, if any; provided that each such new Note will be in a principal amount of not less than $2,000 or an integral multiple of $1,000 in excess thereof. Any Note so accepted for payment will cease to accrue interest on and after the Change of Control Payment Date unless the Issuer defaults in making the Change of Control Payment. The Issuer will publicly announce the results of the Change of Control Offer on or as soon as practicable after the Change of Control Payment Date.

(d) The provisions described herein that require the Issuer to make a Change of Control Offer following a Change of Control Triggering Event will be applicable regardless of whether any other provisions of this Indenture are applicable.

(e) The Issuer will not be required to make a Change of Control Offer upon a Change of Control Triggering Event if (1) a third party makes the Change of Control Offer in the manner, at the times and otherwise in compliance with the requirements set forth in this Indenture applicable to a Change of Control Offer made by the Issuer and purchases all Notes properly tendered and not withdrawn under the Change of Control Offer, or (2) a notice of redemption with respect to the Notes of the applicable series has been given pursuant to this Indenture as described in Section 3.07 and all conditions to any such redemption shall have been satisfied or waived, unless and until there is a default in payment of the Change of Control Payment. A Change of Control Offer may be made in advance of a Change of Control or a Change of Control Triggering Event, and conditioned upon the occurrence of such Change of Control or Change of Control Triggering Event, if a definitive agreement is in place for a Change of Control at the time of making the Change of Control Offer, Notes repurchased by the Issuer pursuant to a Change of Control Offer will have the status of Notes issued but not outstanding or will be retired and cancelled, at the Issuer’s option. Notes purchased by a third party pursuant to this clause (e) will have the status of Notes issued and outstanding.

The provisions in this Section 4.15 relating to the Issuer’s obligation to make an offer to repurchase the Notes of any series as a result of a Change of Control may be waived or modified with the written consent of the Holders of a majority in aggregate principal amount of the Notes of such series then outstanding.

The Trustee shall have no obligation to determine whether a Change of Control Triggering Event or any component thereof has occurred or is continuing, or notify the Holders of a Change of Control Triggering Event.

 

109


Section 4.16 Future Guarantees.

If, on any date (a “Guarantee Date”), the aggregate amount of Indebtedness for borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit of any Restricted Subsidiary that is not a Guarantor or a Non-Recourse Subsidiary then outstanding (other than any such Indebtedness owing to the Issuer or any Guarantor) exceeds the greater of (A) $250.0 million and (B) 7.5% of Distributable Cash for the applicable Test Period (tested at the time of incurrence of the applicable Indebtedness without regard to any subsequent change in Distributable Cash), the Issuer will cause such Restricted Subsidiary to (x) execute and deliver to the Trustee, within 45 days after such Guarantee Date, a supplemental indenture to this Indenture, which shall be substantially in the form attached as Exhibit E hereto, pursuant to which such Restricted Subsidiary will unconditionally guarantee the payment of the Notes, jointly and severally with all other Guarantors (if any) of the Notes, and (y) execute and deliver Security Documents or supplements thereto.

Section 4.17 Designation of Restricted and Unrestricted Subsidiaries.

(a) The Board of Directors of the Issuer may designate any Subsidiary of the Issuer (including any newly acquired or newly formed Subsidiary or a Person becoming a Subsidiary through merger, consolidation or other business combination transaction, or Investment therein), to be an Unrestricted Subsidiary only if:

(1) such Subsidiary or any of its Subsidiaries does not own any Equity Interests or Indebtedness of, or own or hold any Lien on any property of, the Issuer or any other Subsidiary of the Issuer which is not a Subsidiary of the Subsidiary to be so designated or otherwise an Unrestricted Subsidiary; provided that each Subsidiary to be so designated and its Subsidiaries has not at the time of designation, and does not thereafter, create, incur, issue, assume, guarantee or otherwise become directly or indirectly liable with respect to any Indebtedness pursuant to which the lender has recourse to any of the assets of the Issuer or any Restricted Subsidiary (other than Equity Interests in the Unrestricted Subsidiary); and

(2) such designation and the Investment of the Issuer or any of the Restricted Subsidiaries in such Subsidiary complies with Section 4.07.

Any such designation by the Board of Directors of the Issuer shall be evidenced to the Trustee by filing with the Trustee a copy of the resolution of the Board of Directors of the Issuer giving effect to such designation and an Officer’s Certificate certifying that such designation complies with the foregoing conditions.

(b) The Board of Directors of the Issuer may designate any Unrestricted Subsidiary to be a Restricted Subsidiary; provided that immediately after giving effect to such designation (1) no Event of Default would result therefrom and (2) (a) any outstanding Indebtedness of such Unrestricted Subsidiary would be permitted to be incurred by a Restricted Subsidiary under Section 4.09 and shall be deemed to be incurred thereunder, and (b) all Liens encumbering the assets of such Unrestricted Subsidiary would be permitted to be incurred by a Restricted Subsidiary under Section 4.12 and shall be deemed to be incurred thereunder, in each case calculated on a pro forma basis as if such designation had occurred at the beginning of the applicable reference period

 

110


on a pro forma basis taking into account such designation. Any such designation by the Board of Directors of the Issuer shall be evidenced to the Trustee by promptly filing with the Trustee a copy of the resolution of the Board of Directors giving effect to such designation or an Officer’s Certificate certifying that such designation complied with the foregoing provisions.

Section 4.18 Suspension of Certain Covenants.

If on any date following the Issue Date:

(a) the Notes of any series have an Investment Grade Rating from at least one Rating Agency; and

(b) no Event of Default shall have occurred and be continuing under this Indenture (the occurrence of the events described in the foregoing clause (a) and this clause (b) being collectively referred to as a “Covenant Suspension Event”),

then, beginning on that day and subject to the provisions of the following paragraph, the covenants of this Indenture under Sections 4.07, 4.08, 4.09, 4.10, 4.11, 4.16, clause (4) of Section 5.01 and Article 12 will be suspended (the “Suspended Covenants”) with respect to the Notes of such series:

During any period that the foregoing covenants have been suspended with respect to a series of Notes, the Board of Directors of the Issuer may not designate any of the Issuer’s Subsidiaries as Unrestricted Subsidiaries with respect to the Notes of such series.

During the Suspension Period with respect to any series of Notes, the Issuer and its Restricted Subsidiaries will be entitled to incur Liens to the extent provided for in Section 4.12 (including, without limitation, Permitted Liens). Any Permitted Liens that may refer to one or more Suspended Covenants shall be interpreted as though such applicable Suspended Covenant(s) continued to be applicable during the Suspension Period (but solely for purposes of Section 4.12 and the “Permitted Liens” definition and for no other covenant).

Notwithstanding the foregoing, if a Rating Agency withdraws its ratings or downgrades the ratings assigned to the Notes of a series such that the Notes of such series no longer have an Investment Grade Rating from at least one Rating Agency, the foregoing covenants shall be reinstated as of and from the date of such rating decline (the “Reversion Date”) with respect to the Notes of such series. The period of time between the Covenant Suspension Event and the Reversion Date with respect to an applicable series of Notes is referred to in this Indenture as the “Suspension Period” and shall relate solely to such series of Notes. Any Indebtedness incurred during the Suspension Period (or deemed incurred or issued in connection with a Limited Condition Transaction entered into during the Suspension Period) will be classified as having been incurred pursuant to clause (3) of Section 4.09(b)(3) with respect to the applicable series of Notes.

 

111


Solely with respect to any series of Notes for which a Covenant Suspension Event has occurred:

(1) Calculations made after the Reversion Date of the amount available to be made as Restricted Payments under Section 4.07 will be made as though Section 4.07 had been in effect since the Issue Date and prior to, but not during, the Suspension Period (including with respect to a Limited Condition Transaction entered into during the Suspension Period). Accordingly, Restricted Payments made during the Suspension Period will not reduce the amount available to be made as Restricted Payments under Section 4.07(a). In addition, all Investments made during the Suspension Period (or deemed made in connection with a Limited Condition Transaction entered into during the Suspension Period) will be classified to have been made under clause (5) of the definition of “Permitted Investments”;

(2) For purposes of Section 4.08, on the Reversion Date, any consensual encumbrances or consensual restrictions of the type specified in clauses (1) through (4) of Section 4.08(a) entered into during the Suspension Period will be deemed to have been in effect on the Issue Date, so that they are permitted under Section 4.08(b)(4);

(3) For purposes of Section 4.11, any Affiliate Transaction entered into after the Reversion Date pursuant to a contract, agreement, loan, advance or guaranty with, or for the benefit of, any Affiliate of the Issuer entered into during the Suspension Period will be deemed to have been in effect as of the Issue Date for purposes of Section 4.11(b)(4);

(4) For purposes of Section 4.10, the amount of Collateral Excess Proceeds and Excess Proceeds will be reset at zero; and

(5) Notwithstanding that the Suspended Covenants may be reinstated after the Reversion Date, (a) no Default, Event of Default or breach of any kind will be deemed to exist under this Indenture, the Notes or the Guarantees with respect to the Suspended Covenants, and none of the Issuer or any of its Subsidiaries shall bear any liability for any actions taken or events occurring during the Suspension Period, or any actions taken at any time pursuant to any Contractual Obligation arising during any Suspension Period, in each case as a result of a failure to comply with the Suspended Covenants during the Suspension Period (or, upon termination of the Suspension Period or after that time based solely on any action taken or event that occurred during the Suspension Period), and (b) following a Reversion Date, the Issuer and each Restricted Subsidiary will be permitted, without causing a Default or Event of Default, to honor, comply with or otherwise perform any contractual commitments or obligations arising during any Suspension Period and to consummate the transactions contemplated thereby.

Promptly following the occurrence of any Suspension Period or Reversion Date in accordance with this Section 4.18, the Issuer will provide an Officer’s Certificate to the Trustee regarding such occurrence, provided that the failure to so notify the Trustee shall not be a default under this Indenture. The Trustee shall have no obligation to independently determine or verify if a Suspension Period or Reversion Date has occurred or notify the holders of any Suspension Period or Reversion Date. The Trustee may provide a copy of such Officer’s Certificate to any Holder upon request. The Trustee shall have no duty to monitor the ratings of the Notes, and shall not be deemed to have any knowledge of the ratings of the Notes.

 

112


ARTICLE 5

SUCCESSORS

Section 5.01 Merger, Consolidation or Sale of Assets.

(a) The Issuer will not, directly or indirectly: (1) consolidate or merge with or into another Person (whether or not the Issuer is the surviving Person); or (2) sell, assign, transfer, convey or otherwise dispose of all or substantially all of the properties or assets of the Issuer and its Subsidiaries, taken as a whole, in one or more related transactions, to another Person; unless:

(1) either: (a) the Issuer is the surviving Person; or (b) the Person formed by or surviving any such consolidation or merger (if other than the Issuer) or to which such sale, assignment, transfer, conveyance or other disposition has been made is a corporation, partnership or limited liability company organized or existing under the laws of the United States, any state of the United States or the District of Columbia;

(2) the Person formed by or surviving any such consolidation or merger (if other than the Issuer) or the Person to which such sale, assignment, transfer, conveyance or other disposition has been made assumes all the obligations of the Issuer under the Security Documents, the Notes and this Indenture pursuant to a supplemental Indenture or other customary documentation;

(3) immediately after such transaction, no Event of Default exists;

(4) the Issuer, as the case may be, or the Person formed by or surviving any such consolidation or merger (if other than the Issuer), or to which such sale, assignment, transfer, conveyance or other disposition has been made would, on the date of such transaction after giving pro forma effect thereto and any related financing transactions as if the same had occurred at the beginning of the applicable Test Period, (i) be permitted to incur at least $1.00 of additional Indebtedness pursuant to the Holdco Debt Ratio test set forth in Section 4.09(a) or (ii) would have had a Holdco Debt Ratio equal to or less than the actual Holdco Debt Ratio for the applicable Test Period;

(5) the Issuer delivers to the Trustee an Officer’s Certificate and opinion of counsel as to compliance with this Section 5.01(a); and

(6) to the extent any assets of the Person formed by or surviving any such consolidation or merger are assets of the type which would constitute Collateral under the Security Documents, such Person will take such action as may be reasonably necessary to cause such property and assets to be made subject to the Lien of the Security Documents in the manner and to the extent required in this Indenture or any of the Security Documents and shall take all reasonably necessary action required by this Indenture of any of the Security Documents so that such Lien is perfected to the extent required by the Security Documents.

 

113


In addition, the Issuer may not, directly or indirectly, lease all or substantially all of its and its respective Subsidiaries’ properties or assets, in one or more related transactions, to any other Person.

This Section 5.01(a) will not apply to (1) a merger of the Issuer with an Affiliate solely for the purpose of reforming the Issuer in another jurisdiction; (2) any sale, transfer, assignment, conveyance, lease or other disposition of assets between or among the Issuer and any Restricted Subsidiary of the Issuer, including by way of merger or consolidation; (3) a conversion by the Issuer into a corporation, partnership, limited partnership, limited liability company or trust organized or existing under the laws of the jurisdiction of organization of the Issuer or the laws of a jurisdiction in the United States (and, if such entity is not a corporation, a co-obligor of the Notes is a corporation organized or existing under such laws); and (4) a change of the Issuer’s name.

(b) Subject to Section 10.04, no Guarantor will, and the Issuer will not permit any Guarantor to, consolidate or merge with or into or wind up into (whether or not such Guarantor is the surviving Person), or sell, assign, transfer, lease, convey or otherwise dispose of all or substantially all of its properties or assets, in one or more related transactions, to any Person unless:

(1) either: (a) such Guarantor is the surviving Person; or (b) the Person formed by or surviving any such consolidation or merger (if other than such Guarantor) or the Person to which such sale, assignment, transfer, conveyance or other disposition has been made assumes all the obligations of such Guarantor under the Security Documents, the Notes, this Indenture and such Guarantor’s related Guarantee pursuant to supplemental indenture or other customary documentation;

(2) immediately after such transaction, no Event of Default exists;

(3) the Issuer delivers to the Trustee an Officer’s Certificate and an Opinion of Counsel as to compliance with this Section 5.01(b); and

(4) to the extent any assets of the Person formed by or surviving any such consolidation or merger are assets of the type which would constitute Collateral under the Security Documents, such Person will take such action as may be reasonably necessary to cause such property and assets to be made subject to the Lien of the Security Documents in the manner and to the extent required in this Indenture or any of the Security Documents and shall take all reasonably necessary action required by this Indenture of any of the Security Documents so that such Lien is perfected to the extent required by the Security Documents; or

(A) the transaction is not prohibited by Section 4.10(a); or

(B) in the case of assets comprised of Equity Interests of Subsidiaries that are not Guarantors, such Equity Interests are sold, assigned, transferred, leased, conveyed or otherwise disposed of to one or more Restricted Subsidiaries, provided that if such Equity Interests constitute Collateral they will continue to constitute Collateral following such disposition.

 

114


This Section 5.01(b) will not apply to (1) a merger of the Guarantor with an Affiliate solely for the purpose of reforming the Guarantor in another jurisdiction, (2) any sale, transfer, assignment, conveyance, lease or other disposition of assets between or among the Issuer or a Guarantor, (3) a conversion by the Guarantor into a corporation, partnership, limited partnership, limited liability company or trust organized or existing under the laws of the jurisdiction of organization of such Guarantor, or (4) a liquidation or dissolution or change of the Guarantor’s legal form if the Issuer determines in good faith that such action is in the best interests of the Issuer, in each case, without regard to the requirements set forth in the preceding paragraph.

Section 5.02 Successor Corporation Substituted

Upon any consolidation or merger, or any sale, assignment, transfer, lease, conveyance or other disposition of all or substantially all of the properties or assets of the Issuer or any Guarantor in a transaction that is subject to, and that complies with the provisions of, Section 5.01 hereof, the successor Person formed by such consolidation or into or with which the Issuer or such Guarantor, as the case may be, is merged or to which such sale, assignment, transfer, lease, conveyance or other disposition is made shall succeed to, and be substituted for (so that from and after the date of such consolidation, merger, sale, assignment, transfer, lease, conveyance or other disposition, the provisions of this Indenture referring to the “Issuer” or such “Guarantor” shall refer instead to the successor Person and not to the Issuer or such Guarantor), and may exercise every right and power of the Issuer or such Guarantor, as the case may be, under this Indenture or the Guarantees, as the case may be, with the same effect as if such successor Person had been named as the Issuer or such Guarantor, as the case may be, herein or the Guarantees, as the case may be. When a successor Person assumes all obligations of its predecessor hereunder, the Notes or the Guarantees, as the case may be, such predecessor shall be released from all obligations; provided that in the event of a transfer or lease, the predecessor shall not be released from the payment of principal and interest or other obligations on the Notes or the Guarantees, as the case may be.

ARTICLE 6

DEFAULTS AND REMEDIES

Section 6.01 Events of Default.

Each of the following is an “Event of Default” with respect to the Notes of any series:

(a) default for 30 days in the payment when due of interest on such Notes;

(b) default in the payment when due of the principal of, or premium, if any, on such Notes;

(c) failure by the Issuer for 180 days after receipt of written notice given by the Trustee to the Issuer or Holders of at least 30% in aggregate principal amount of the Notes of such series then outstanding voting as a single class to the Issuer and the Trustee, to comply with Section 4.03;

(d) failure by the Issuer or any Guarantor for 60 days after receipt of written notice given by the Trustee to the Issuer or Holders of at least 30% in aggregate principal amount of Notes of such series then outstanding voting as a single class to the Issuer and the Trustee, to comply with any of the agreements in this Indenture other than those described in clauses (a), (b) and (c) of this Section 6.01;

 

115


(e) default under any mortgage, indenture or instrument under which there is issued or by which there is secured or evidenced any Indebtedness for money borrowed by the Issuer or any Restricted Subsidiary (other than a Non-Recourse Subsidiary), or the payment of which is guaranteed by the Issuer or any Restricted Subsidiary (other than a Non-Recourse Subsidiary), whether such Indebtedness or guarantee now exists, or is created after the Issue Date, if both:

(1) such default either results from the failure to pay principal on such Indebtedness at its stated final maturity (after giving effect to any applicable grace periods) or relates to an obligation other than the obligation to pay principal of any such Indebtedness at its stated final maturity and results in the holder or holders of such Indebtedness causing such Indebtedness to become due prior to its stated final maturity; and

(2) the principal amount of any such Indebtedness, together with the principal amount of any other such Indebtedness in default for failure to pay principal at stated final maturity (after giving effect to applicable grace periods), or the maturity of which has been so accelerated, exceeds the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period,

provided that this clause (e) shall not apply to secured Indebtedness that becomes due as a result of the voluntary sale or transfer of the property or assets securing such Indebtedness to a Person that is not an Affiliate of the Issuer;

(f) one or more judgments for the payment of money in an aggregate amount in excess of the greater of (A) $100.0 million and (B) 3.0% of Distributable Cash for the applicable Test Period (excluding therefrom any amount reasonably expected to be covered by insurance) shall be rendered against the Issuer or any Restricted Subsidiary (other than a Non-Recourse Subsidiary) or any combination thereof and the same shall not have been paid, discharged or stayed for a period of 60 days after such judgment became final and non-appealable;

(g) except as permitted by this Indenture, any Guarantee of the Notes of such series shall be held in any final and non-appealable judgment to be unenforceable or invalid or shall cease for any reason to be in full force and effect;

(h) the Issuer or any Guarantor pursuant to or within the meaning of Bankruptcy Law:

(1) commences a voluntary case,

(2) consents to the entry of an order for relief against it in an involuntary case,

(3) consents to the appointment of a custodian of it or for all or substantially all of its property,

(4) makes a general assignment for the benefit of its creditors, or

 

116


(5) generally is not paying its debts as they become due;

(i) a court of competent jurisdiction enters an order or decree under any Bankruptcy Law that:

(1) is for relief against the Issuer or any Guarantor in an involuntary case;

(2) appoints a custodian of the Issuer or any Guarantor; or

(3) orders the liquidation of the Issuer or any Guarantor;

and the order or decree remains unstayed and in effect for 60 consecutive days; and

(j) other than by reason of the satisfaction in full of all obligations under this Indenture and discharge of this Indenture with respect to the Notes of such series or the release of the Collateral with respect to the Notes of such series in accordance with the terms of this Indenture and the Security Documents, (i)(A) in the case of any security interest with respect to any material portion of the Collateral, such security interest under the Security Documents shall, at any time, cease to be a valid and perfected security interest or shall be declared invalid or unenforceable except to the extent that any such perfection or priority is not required pursuant to the Security Documents or this Indenture or the Issuer or the relevant Guarantor, as applicable, has delivered all required certificates representing securities pledged under the Security Documents to the Collateral Agent, or (B) in the case of any security interest with respect to any material portion of the Collateral, the Issuer or any Guarantor shall assert, in any pleading in any court of competent jurisdiction, that any security interest under any Security Document is invalid or unenforceable, and (ii) such default continues for 30 days after receipt of written notice given by the Trustee to the Issuer or the Holders of not less than 30% in aggregate principal amount of the then outstanding Notes of such series to the Issuer and the Trustee.

Section 6.02 Acceleration.

In the case of an Event of Default with respect to the Notes of any series specified in clause (h) or (i) of Section 6.01 hereof with respect to the Issuer, all outstanding Notes of such series will become due and payable immediately without further action or notice. If any other Event of Default occurs and is continuing, the Trustee by written notice to the Issuer or the Holders of at least 30% in aggregate principal amount of the then outstanding Notes of such series by written notice to the Issuer and the Trustee, may declare all the Notes of such series to be due and payable immediately. Upon any such declaration, the Notes of such series shall become due and payable immediately.

The Holders of a majority in aggregate principal amount of the then outstanding Notes of a series by written notice to the Issuer and the Trustee, and the Trustee may, on behalf of the Holders of all the Notes of such series, rescind an acceleration and its consequences hereunder, if the rescission would not conflict with any judgment or decree and if all existing Events of Default (except nonpayment of principal of, premium on, if any, or interest, if any, on the Notes of such series that has become due solely because of the declaration of acceleration) have been cured or waived.

 

117


In the event of a declaration of acceleration of the Notes of any series because an Event of Default described in clause (e) of Section 6.01 has occurred and is continuing, the declaration of acceleration of the Notes of such series shall be automatically annulled if the default triggering such Event of Default pursuant to such clause (e) of Section 6.01 shall be remedied or cured, or waived by the holders of the Indebtedness with respect to which such default has occurred within 30 days after the declaration of acceleration of such Notes; provided that (a)(1) the annulment of the acceleration of the Notes of such series would not conflict with any judgment or decree of a court of competent jurisdiction and (2) all existing Events of Default, except nonpayment of principal, premium or interest on the Notes of such series that became due solely because of the acceleration of the Notes of such series, have been cured or waived, (b) the Indebtedness or guarantee that is the basis for such Event of Default has been discharged, or (c) the requisite number of holders thereof have rescinded or waived the acceleration, notice or action (as the case may be) giving rise to such Event of Default.

If a Default occurs for a failure to report or deliver a required certificate in connection with another default (an “Initial Default”) then at the time such Initial Default is cured, such Default for a failure to report or deliver a required certificate in connection with the Initial Default will also be cured without any further action and any Default or Event of Default for the failure to comply with the time periods prescribed in Section 4.03 or otherwise to deliver any notice or certificate pursuant to any other provision of this Indenture shall be deemed to be cured upon the delivery of any such report required by such covenant or notice or certificate, as applicable, even though such delivery is not within the prescribed period specified in this Indenture.

Any notice of an Event of Default, notice of acceleration or instruction to the Trustee to provide a notice of an Event of Default, notice of acceleration or take any other action in connection with an Event of Default and/or acceleration of the Notes of a series (a “Noteholder Direction”) provided by any one or more holders (each a “Directing Holder”) must be accompanied by a written representation from each such holder of Notes of such series delivered to the Issuer and the Trustee that such holder is not (or, in the case such holder is DTC, or its nominee, that such holder is being instructed solely by beneficial owners that have represented to such holder that they are not) Net Short (a “Position Representation”), which representation, in the case of a Noteholder Direction relating to the delivery of a notice of an Event of Default shall be deemed a continuing representation until the resulting Event of Default is cured or otherwise ceases to exist or such Notes are accelerated. In addition, each Directing Holder is deemed, at the time of providing a Noteholder Direction, to covenant to provide the Issuer with such other information as the Issuer may reasonably request from time to time in order to verify the accuracy of such holder’s Position Representation within five Business Days of request therefor (a “Verification Covenant”). In any case in which the holder is DTC, or its nominee, any Position Representation or Verification Covenant required hereunder shall be provided by the beneficial owner of such Notes in lieu of DTC, or its nominee, and DTC shall be entitled to conclusively rely on such Position Representation and Verification Covenant in delivering its direction to the Trustee.

If, following the delivery of a Noteholder Direction, but prior to acceleration of the Notes of a series, the Issuer determines in good faith that there is a reasonable basis to believe a Directing Holder was, at any relevant time, in breach of its Position Representation and provides to the Trustee an Officer’s Certificate stating that the Issuer has initiated litigation in a court of competent jurisdiction seeking a determination that such Directing Holder was, at such time, in breach of its

 

118


Position Representation, and seeking to invalidate any Event of Default that resulted from the applicable Noteholder Direction, the cure period with respect to such Event of Default shall be automatically stayed and the cure period with respect to such Event of Default shall be automatically reinstituted and any remedy stayed pending a final and non-appealable determination of a court of competent jurisdiction on such matter (a “Court Determination”). If, following the delivery of a Noteholder Direction, but prior to acceleration of the Notes of such series, the Issuer provides to the Trustee an Officer’s Certificate stating that a Directing Holder failed to satisfy its Verification Covenant, the cure period with respect to such Event of Default shall be automatically stayed and the cure period with respect to any Event of Default that resulted from the applicable Noteholder Direction shall be automatically reinstituted and any remedy stayed pending satisfaction of such Verification Covenant, and confirmation of such satisfaction shall be provided in writing by the Issuer to the Trustee. Any breach of the Position Representation (as confirmed by a Court Determination) shall result in such holder’s participation in such Noteholder Direction being disregarded; and, if, without the participation of such noteholder, the percentage of Notes of such series held by the remaining noteholders that provided such Noteholder Direction would have been insufficient to validly provide such Noteholder Direction, such Noteholder Direction shall be void ab initio, with the effect that such Event of Default shall be deemed never to have occurred, acceleration voided and the Trustee shall be deemed not to have received such Noteholder Direction or any notice of such Event of Default; provided, however, that this shall not invalidate any indemnity or security provided by any Directing Holder to the Trustee.

Notwithstanding anything in the preceding two paragraphs to the contrary, any Noteholder Direction delivered to the Trustee during the pendency of an Event of Default as the result of a bankruptcy or similar proceeding shall not require compliance with the foregoing paragraphs. For the avoidance of doubt, the Trustee shall be entitled to conclusively rely on any Noteholder Direction, Position Representation, Verification Covenant, Officer’s Certificate or other document delivered to it in accordance with this Indenture, shall have no duty to monitor, inquire as to or investigate the accuracy of, or compliance with, any Position Representation or any Verification Covenant, verify any statements in any Officer’s Certificate delivered to it, or otherwise make calculations, investigations or determinations or take any other actions with respect to Derivative Instruments, Net Shorts, Long Derivative Instruments, Short Derivative Instruments or otherwise. The Trustee shall have no liability to the Issuer, any holder or any other Person in acting in good faith pursuant to a Noteholder Direction without regard to any Position Representation or compliance with any Verification Covenant, and all such parties agree not to commence any legal proceedings against the Trustee in respect of, and agree that the Trustee will not be liable for, the delivery and accuracy of, or compliance with, any Position Representation or any Verification Covenant.

Section 6.03 Other Remedies.

If an Event of Default occurs and is continuing with respect to the Notes of any series, the Trustee may pursue any available remedy to collect the payment of principal of, premium on, if any, or interest, if any, on the Notes of such series or to enforce the performance of any provision of the Notes of such series or this Indenture.

 

119


The Trustee may maintain a proceeding even if it does not possess any of the Notes of a series or does not produce any of them in the proceeding. A delay or omission by the Trustee or any Holder in exercising any right or remedy accruing upon an Event of Default shall not impair the right or remedy or constitute a waiver of or acquiescence in the Event of Default. All remedies are cumulative to the extent permitted by law.

Section 6.04 Waiver of Past Defaults.

The Holders of at least a majority in aggregate principal amount of the then outstanding Notes voting as a class by written notice to the Trustee may, on behalf of the Holders of all of the Notes waive any existing Default or Event of Default and its consequences hereunder, except a continuing Default in the payment of principal of, premium on, if any, or interest, if any, on, any Note held by a non-consenting Holder (including in connection with an offer to purchase); provided, however, that the Holders of a majority in aggregate principal amount of the then outstanding Notes may rescind an acceleration and its consequences, including any related payment default that resulted from such acceleration. If any waiver will only affect one series of Notes (or less than all series of Notes) then outstanding under this Indenture, then only the waiver of the holders of a majority in principal amount of the Notes of such series then outstanding (including, in each case, consents obtained in connection with a purchase of, or tender offer or exchange offer for, any such Notes) shall be required and (y) if any such waiver by its terms will affect a series of Notes in a manner different and materially adverse relative to the manner such amendment or waiver affects other series of Notes, then the waiver of the holders of a majority in principal amount of the Notes of such series then outstanding (including, in each case, consents obtained in connection with a purchase of, or tender offer or exchange offer for, any such Notes) shall be required. Upon any such waiver, such Default shall cease to exist, and any Event of Default arising therefrom shall be deemed to have been cured for every purpose of this Indenture; but no such waiver shall extend to any subsequent or other Default or impair any right consequent thereon.

Section 6.05 Control by Majority.

Holders of a majority in aggregate principal amount of the then outstanding Notes of a series may direct the time, method and place of conducting any proceeding for exercising any remedy available to the Trustee or the Collateral Agent or exercising any trust or power conferred on it with respect to such series of Notes. However, the Trustee or the Collateral Agent may refuse to follow any direction that conflicts with law or this Indenture, or that that the Trustee or the Collateral Agent determines may be unduly prejudicial to the rights of other Holders of Notes of such series or that may involve the Trustee or the Collateral Agent in personal liability.

Section 6.06 Limitation on Suits.

Except to enforce the contractual right to receive payment of principal, premium, if any, or interest when due on or after the respective due dates expressed in an outstanding Note, no Holder of a Note may pursue any remedy with respect to this Indenture or the Notes unless:

(a) such Holder has previously given the Trustee written notice that an Event of Default is continuing;

 

120


(b) Holders of at least 30% in aggregate principal amount of the then outstanding Notes of the applicable series make a written request to the Trustee to pursue the remedy;

(c) such Holder or Holders offer and, if requested, provide to the Trustee security or indemnity reasonably satisfactory to the Trustee against any loss, liability or expense;

(d) the Trustee has not complies with such request within 60 days after receipt of the request and the offer of security or indemnity; and

(e) during such 60-day period, Holders of a majority in aggregate principal amount of the then outstanding Notes of the applicable series do not give the Trustee a direction inconsistent with such written request within such 60 day period.

A Holder may not use this Indenture to prejudice the rights of another Holder or to obtain a preference or priority over another Holder.

Section 6.07 Rights of Holders of Notes to Receive Payment.

Notwithstanding any other provision of this Indenture, the right of any Holder to receive payment of principal of, premium on, if any, or interest, if any, on a Note of any series, on or after the respective due dates expressed in such Note (including in connection with an offer to purchase), or to bring suit for the enforcement of any such payment on or after such respective dates, shall not be impaired or affected without the consent of such Holder.

Section 6.08 Collection Suit by Trustee.

If an Event of Default specified in Section 6.01(a) or (b) hereof occurs and is continuing with respect to the Notes of any series, the Trustee is authorized to recover judgment in its own name and as trustee of an express trust against the Issuer for the whole amount of principal of, premium on, if any, and interest, if any, remaining unpaid on the Notes of such series and interest on overdue principal and, to the extent lawful, interest and such further amount as shall be sufficient to cover the costs and expenses of collection, including the reasonable compensation, expenses, disbursements and advances of the Trustee, the Agents and their respective agents and counsel.

If the Trustee or any Holder has instituted any proceeding to enforce any right or remedy under this Indenture and such proceeding has been discontinued or abandoned for any reason, or has been determined adversely to the Trustee or to such Holder, then and in every such case, subject to any determination in such proceedings, the Issuer, the Trustee and the Holders shall be restored severally and respectively to their former positions hereunder and thereafter all rights and remedies of the Trustee and the Holders shall continue as though no such proceeding has been instituted.

Section 6.09 Trustee May File Proofs of Claim.

The Trustee is authorized to file such proofs of claim and other papers or documents as may be necessary or advisable in order to have the claims of the Trustee (including any claim for the reasonable compensation, expenses, disbursements and advances of the Trustee, its agents and

 

121


counsel) and the Holders allowed in any judicial proceedings relative to the Issuer (or any other obligor upon the Notes), its creditors or its property and shall be entitled and empowered to collect, receive and distribute any money or other property payable or deliverable on any such claims and any custodian in any such judicial proceeding is hereby authorized by each Holder to make such payments to the Trustee, and in the event that the Trustee shall consent to the making of such payments directly to the Holders, to pay to the Trustee any amount due to it for the reasonable compensation, expenses, disbursements and advances of the Trustee, the Agents and their respective agents and counsel, and any other amounts due the Trustee under Section 7.06 hereof. To the extent that the payment of any such compensation, expenses, disbursements and advances of the Trustee, the Agents and their respective agents and counsel, and any other amounts due the Trustee under Section 7.06 hereof out of the estate in any such proceeding, shall be denied for any reason, payment of the same shall be secured by a Lien on, and shall be paid out of, any and all distributions, dividends, money, securities and other properties that the Holders may be entitled to receive in such proceeding whether in liquidation or under any plan of reorganization or arrangement or otherwise. Nothing herein contained shall be deemed to authorize the Trustee to authorize or consent to or accept or adopt on behalf of any Holder any plan of reorganization, arrangement, adjustment or composition affecting the Notes of any series or the rights of any Holder, or to authorize the Trustee to vote in respect of the claim of any Holder in any such proceeding.

Section 6.10 Priorities.

Subject to any First Lien Intercreditor Agreement, if the Trustee collects any money or property pursuant to this Article 6 or pursuant to the Security Documents, it shall pay out the money or property in the following order:

First: to the Trustee and to the Collateral Agent, in each case, and their respective agents and attorneys for amounts due under Section 7.06 hereof, including payment of all compensation, expenses and liabilities incurred, and all advances made, by the Trustee and the Collateral Agent and the costs and expenses of collection;

Second: to Holders for amounts due and unpaid on the Notes for principal, premium, if any, and interest, if any, ratably, without preference or priority of any kind, according to the amounts due and payable on the Notes for principal, premium, if any, and interest, if any, respectively; and

Third: to the Issuer or to such party as a court of competent jurisdiction shall direct, including a Guarantor, if applicable

The Trustee may fix a record date and payment date for any payment to Holders of Notes of any series pursuant to this Section 6.10.

Section 6.11 Undertaking for Costs.

In any suit for the enforcement of any right or remedy under this Indenture or in any suit against the Trustee for any action taken or omitted by it as a Trustee, a court in its discretion may require the filing by any party litigant in the suit of an undertaking to pay the costs of the suit, and the court in its discretion may assess reasonable costs, including reasonable attorneys’ fees, against any party litigant in the suit, having due regard to the merits and good faith of the claims or defenses made by the party litigant. This Section 6.11 does not apply to a suit by the Trustee, a suit by a Holder pursuant to Section 6.07 hereof, or a suit by Holders of more than 10% in aggregate principal amount of the then outstanding Notes of a series.

 

122


ARTICLE 7

TRUSTEE

Section 7.01 Duties of Trustee.

(a) If an Event of Default has occurred and is continuing, the Trustee will exercise such of the rights and powers vested in it by this Indenture, and use the same degree of care and skill in its exercise, as a prudent person would exercise or use under the circumstances in the conduct of such person’s own affairs.

(b) Except during the continuance of an Event of Default:

(1) the duties of the Trustee will be determined solely by the express provisions of this Indenture and the Trustee need perform only those duties that are specifically set forth in this Indenture and no others, and no implied covenants or obligations shall be read into this Indenture against the Trustee; and

(2) in the absence of bad faith on its part, the Trustee may conclusively rely, as to the truth of the statements and the correctness of the opinions expressed therein, upon certificates or opinions furnished to the Trustee and conforming to the requirements of this Indenture. However, the Trustee will examine the certificates and opinions to determine whether or not they conform to the requirements of this Indenture.

(c) The Trustee may not be relieved from liabilities for its own negligent action, its own negligent failure to act, or its own willful misconduct, except that:

(1) this paragraph does not limit the effect of paragraph (b) of this Section 7.01;

(2) the Trustee will not be liable for any error of judgment made in good faith by a Responsible Officer, unless it is proved that the Trustee was negligent in ascertaining the pertinent facts; and

(3) the Trustee will not be liable with respect to any action it takes or omits to take in good faith in accordance with a direction received by it pursuant to Section 6.05 hereof.

(d) Whether or not therein expressly so provided, every provision of this Indenture that in any way relates to the Trustee is subject to this Section 7.01.

(e) No provision of this Indenture will require the Trustee to expend or risk its own funds or incur any liability. The Trustee will be under no obligation to exercise any of its rights or powers under this Indenture at the request of any Holders, unless such Holder has offered to the Trustee security and indemnity satisfactory to it against any loss, liability or expense.

 

123


(f) The Trustee will not be liable for interest on any money received by it except as the Trustee may agree in writing with the Issuer. Money held in trust by the Trustee need not be segregated from other funds except to the extent required by law.

Section 7.02 Rights of Trustee.

(a) The Trustee may conclusively rely upon any document believed by it to be genuine and to have been signed or presented by the proper Person. The Trustee need not investigate any fact or matter stated in the document.

(b) Before the Trustee acts or refrains from acting, it may require an Officer’s Certificate or an Opinion of Counsel or both. The Trustee will not be liable for any action it takes or omits to take in good faith in reliance on such Officer’s Certificate or Opinion of Counsel. The Trustee may consult with counsel and the written advice of such counsel or any Opinion of Counsel will be full and complete authorization and protection from liability in respect of any action taken, suffered or omitted by it hereunder in good faith and in reliance thereon.

(c) The Trustee may act through its attorneys and agents and will not be responsible for the misconduct or negligence of any agent appointed with due care.

(d) The Trustee will not be liable for any action it takes or omits to take in good faith that it believes to be authorized or within the rights or powers conferred upon it by this Indenture.

(e) Unless otherwise specifically provided in this Indenture, any demand, request, direction or notice from the Issuer will be sufficient if signed by an Officer of the Issuer.

(f) The Trustee will be under no obligation to exercise any of the rights or powers vested in it by this Indenture at the request or direction of any of the Holders unless such Holders have offered to the Trustee indemnity or security satisfactory to the Trustee against the losses, liabilities and expenses that might be incurred by it in compliance with such request or direction.

(g) The Trustee shall not be deemed to have notice of any Default hereunder or Event of Default unless a Responsible Officer of the Trustee has actual knowledge thereof or unless written notice of any event which is in fact such a Default or Event of Default is received by a Responsible Officer at the Corporate Trust Office of the Trustee, and such notice references the Notes and this Indenture.

(h) The rights, privileges, protections, immunities and benefits given to the Trustee, including, without limitation, its right to be indemnified, are extended to, and shall be enforceable by, the Trustee in each of its capacities hereunder.

(i) In no event shall the Trustee be responsible or liable for special, punitive, indirect, or consequential loss or damage of any kind whatsoever (including, but not limited to, loss of profit) irrespective of whether the Trustee has been advised of the likelihood of such loss or damage and regardless of the form of action.

 

124


(j) The Trustee may request that the Issuer deliver an Officer’s Certificate setting forth the names of individuals and/or titles of officers authorized at such time to take specified actions pursuant to this Indenture, which Officer’s Certificate may be signed by any person authorized to sign an Officer’s Certificate, including any person specified as so authorized in any such certificate previously delivered and not superseded.

(k) In no event shall the Trustee be responsible or liable for any failure or delay in the performance of its obligations hereunder arising out of or caused by, directly or indirectly, forces beyond its control, including, without limitation, strikes, work stoppages, accidents, acts of war or terrorism, civil or military disturbances, nuclear or natural catastrophes or acts of God, and interruptions, loss or malfunctions of utilities, communications or computer (software and hardware) services; it being understood that the Trustee shall use reasonable efforts which are consistent with accepted practices in the banking industry to resume performance as soon as practicable under the circumstances.

(l) The parties hereto acknowledge that in accordance with Section 326 of the U.S.A. PATRIOT Act, the Trustee, like all financial institutions and in order to help fight the funding of terrorism and money laundering, is required to obtain, verify, and record information that identifies each person or legal entity that establishes a relationship or opens an account with the Trustee. The parties to this Indenture agree that they will provide the Trustee with such information as it may request in order for the Trustee to satisfy the requirements of the U.S.A. PATRIOT Act.

(m) The Trustee shall have the right to accept and act upon instructions, including funds transfer instructions (“Instructions”) given pursuant to this Indenture and any other Transaction Document and delivered using Electronic Means; provided, however, that the Issuer and the Guarantors shall provide to the Trustee an incumbency certificate listing officers with the authority to provide such Instructions (“Instructing Officers”) and containing specimen signatures of such Instructing Officers, which incumbency certificate shall be amended by the Issuer and/or the Guarantors, as applicable, whenever a person is to be added or deleted from the listing. If the Issuer and/or the Guarantors, as applicable, elects to give the Trustee Instructions using Electronic Means and the Trustee in its discretion elects to act upon such Instructions, the Trustee’s understanding of such Instructions shall be deemed controlling. The Issuer and the Guarantors understand and agree that the Trustee cannot determine the identity of the actual sender of such Instructions and that the Trustee shall conclusively presume that directions that purport to have been sent by an Instructing Officer listed on the incumbency certificate provided to the Trustee have been sent by such Instructing Officer. The Issuer and the Guarantors shall be responsible for ensuring that only Instructing Officers transmit such Instructions to the Trustee and that the Issuer, the Guarantors and all Instructing Officers are solely responsible to safeguard the use and confidentiality of applicable user and authorization codes, passwords and/or authentication keys upon receipt by the Issuer and/or the Guarantors, as applicable. The Trustee shall not be liable for any losses, costs or expenses arising directly or indirectly from the Trustee’s reliance upon and compliance with such Instructions notwithstanding such directions conflict or are inconsistent with a subsequent written instruction. The Issuer and the Guarantors agree: (i) to assume all risks arising out of the use of Electronic Means to submit Instructions to the Trustee, including without limitation the risk of the Trustee acting on unauthorized Instructions, and the risk of interception and misuse by third parties; (ii) that it is fully informed of the protections and risks associated with the various methods of transmitting Instructions to the Trustee and that there may be more secure methods of transmitting Instructions than the method(s) selected by the Issuer and/or the Guarantors, as applicable; (iii) that the security procedures (if any) to be followed in connection with its transmission of Instructions provide to it a commercially reasonable degree of protection in light of its particular needs and circumstances; and (iv) to notify the Trustee immediately upon learning of any compromise or unauthorized use of the security procedures.

 

125


Section 7.03 Individual Rights of Trustee.

The Trustee in its individual or any other capacity may become the owner or pledgee of Notes and may otherwise deal with the Issuer or any Affiliate of the Issuer with the same rights it would have if it were not Trustee. However, in the event that the Trustee acquires any conflicting interest it must eliminate such conflict within 90 days or resign. Any Agent may do the same with like rights and duties. The Trustee is also subject to Section 7.09 hereof

Section 7.04 Trustees Disclaimer.

The Trustee will not be responsible for and makes no representation as to the validity or adequacy of this Indenture or the Notes, it shall not be accountable for the Issuer’s use of the proceeds from the Notes or any money paid to the Issuer or upon the Issuer’s direction under any provision of this Indenture, it will not be responsible for the use or application of any money received by any Paying Agent other than the Trustee, and it will not be responsible for any statement or recital herein or any statement in the Notes or any other document in connection with the sale of the Notes or pursuant to this Indenture other than its certificate of authentication.

Section 7.05 Notice of Defaults.

If a Default or Event of Default occurs and is continuing and if it is known to a Responsible Officer of the Trustee as described in Section 7.02(g), the Trustee will deliver (or, in the case of Global Notes, transmit pursuant to the Applicable Procedures) to Holders of Notes a notice of the Default or Event of Default within 90 days after it occurs, unless such Default shall have been cured or waived, or if discovered after 90 days, promptly thereafter. Except in the case of a Default or Event of Default in payment of principal of, premium on, if any, interest, if any, on, any Note, the Trustee may withhold the notice if and so long as a committee of its Responsible Officers in good faith determines that withholding the notice is in the interests of the Holders.

Section 7.06 Compensation and Indemnity.

(a) The Issuer will pay to the Trustee from time to time reasonable compensation for its acceptance of this Indenture and services hereunder as agreed in writing between the Issuer and the Trustee. The Trustee’s compensation will not be limited by any law on compensation of a trustee of an express trust. The Issuer will reimburse the Trustee promptly upon request for all reasonable disbursements, advances and expenses incurred or made by it in addition to the compensation for its services. Such expenses will include the reasonable compensation, disbursements and expenses of the Trustee’s agents and counsel.

(b) The Issuer and the Guarantors will, jointly and severally, indemnify the Trustee against any and all losses, liabilities or expenses incurred by it arising out of or in connection with the acceptance or administration of its duties under this Indenture, including the costs and expenses of enforcing this Indenture against the Issuer and the Guarantors (including this Section 7.06) and defending itself against any claim (whether asserted by the Issuer, the Guarantors, any Holder or

 

126


any other Person) or liability in connection with the exercise or performance of any of its powers or duties hereunder, except to the extent any such loss, liability or expense may be attributable to its own gross negligence or willful misconduct, as determined by a final, non-appealable decision of a court of competent jurisdiction. The Trustee will notify the Issuer promptly of any claim for which it may seek indemnity. Failure by the Trustee to so notify the Issuer will not relieve the Issuer or any of the Guarantors of their obligations hereunder. Neither the Issuer nor any Guarantor need pay for any settlement made without its consent, which consent will not be unreasonably withheld, conditioned or delayed.

(c) The obligations of the Issuer and the Guarantors under this Section 7.06 will survive the satisfaction and discharge of this Indenture.

(d) To secure the Issuer’s and the Guarantors’ payment obligations in this Section 7.06, the Trustee will have a Lien prior to the Notes on all money or property held or collected by the Trustee, except that held in trust to pay principal of, premium on, if any, interest, if any, on, particular Notes. Such Lien will survive the satisfaction and discharge of this Indenture.

(e) When the Trustee incurs expenses or renders services after an Event of Default specified in clause (h) or (i) of Section 6.01 hereof occurs, the expenses and the compensation for the services (including the fees and expenses of its agents and counsel) are intended to constitute expenses of administration under any Bankruptcy Law.

Section 7.07 Replacement of Trustee.

(a) A resignation or removal of the Trustee and appointment of a successor Trustee will become effective only upon the successor Trustee’s acceptance of appointment as provided in this Section 7.07.

(b) The Trustee may resign in writing at any time and be discharged from the trust hereby created by so notifying the Issuer. The Holders of a majority in aggregate principal amount of the then outstanding Notes may remove the Trustee by so notifying the Trustee and the Issuer in writing. The Issuer may remove the Trustee if:

(1) the Trustee fails to comply with Section 7.09 hereof;

(2) the Trustee is adjudged a bankrupt or an insolvent or an order for relief is entered with respect to the Trustee under any Bankruptcy Law;

(3) a custodian or public officer takes charge of the Trustee or its property; or

(4) the Trustee becomes incapable of acting.

(c) If the Trustee resigns or is removed or if a vacancy exists in the office of Trustee for any reason, the Issuer will promptly appoint a successor Trustee. Within one year after the successor Trustee takes office, the Holders of a majority in aggregate principal amount of the then outstanding Notes may appoint a successor Trustee to replace the successor Trustee appointed by the Issuer.

 

127


(d) If a successor Trustee does not take office within 60 days after the retiring Trustee resigns or is removed, the retiring Trustee, the Issuer, or the Holders of at least 10% in aggregate principal amount of the then outstanding Notes may petition any court of competent jurisdiction for the appointment of a successor Trustee.

(e) If the Trustee, after written request by any Holder who has been a Holder for at least six months, fails to comply with Section 7.09 hereof, such Holder may petition any court of competent jurisdiction for the removal of the Trustee and the appointment of a successor Trustee.

(f) A successor Trustee will deliver a written acceptance of its appointment to the retiring Trustee and to the Issuer. Thereupon, the resignation or removal of the retiring Trustee will become effective, and the successor Trustee will have all the rights, powers and duties of the Trustee under this Indenture. The successor Trustee will mail a notice of its succession to Holders. The retiring Trustee will promptly transfer all property held by it as Trustee to the successor Trustee; provided all sums owing to the Trustee hereunder have been paid and subject to the Lien provided for in Section 7.06 hereof Notwithstanding replacement of the Trustee pursuant to this Section 7.07, the Issuer’s obligations under Section 7.06 hereof will continue for the benefit of the retiring Trustee.

Section 7.08 Successor Trustee by Merger, etc.

If the Trustee consolidates, merges or converts into, or transfers all or substantially all of its corporate trust business to, another corporation, the successor corporation without any further act will be the successor Trustee.

Section 7.09 Eligibility; Disqualification.

There will at all times be a Trustee hereunder that is a corporation organized and doing business under the laws of the United States of America or of any state thereof that is authorized under such laws to exercise corporate trust powers, that is subject to supervision or examination by federal or state authorities and that has a combined capital and surplus of at least $100.0 million as set forth in its most recent published annual report of condition.

Section 7.10 Security Documents.

By their acceptance of the Notes, the Holders hereby authorize and direct the Trustee and the Collateral Agent to execute and deliver this Indenture, the Security Documents in which the Trustee or the Collateral Agent is named as a party, including any Security Documents executed on or after the Issue Date. It is hereby expressly acknowledged and agreed that, in doing so, the Trustee and the Collateral Agent are not responsible for the terms or contents of such agreements, or for the validity or enforceability thereof, or the sufficiency thereof for any purpose. Whether or not so expressly stated therein, in entering into, or taking (or forbearing from) any action under, this Indenture, the Security Documents, the Trustee and the Collateral Agent each shall have all of the rights, privileges, benefits, immunities, indemnities and other protections granted to it under this Indenture (in the case of the Trustee) and the Collateral Agency Agreement (in the case of the Collateral Agent) (in addition to those that may be granted to it under the terms of such other agreement or agreements).

 

128


ARTICLE 8

LEGAL DEFEASANCE AND COVENANT DEFEASANCE

Section 8.01 Option to Effect Legal Defeasance or Covenant Defeasance.

The Issuer may, at the option of its Board of Directors evidenced by a resolution set forth in an Officer’s Certificate, at any time, elect to have either Section 8.02 or 8.03 hereof be applied to all outstanding Notes of a series upon compliance with the conditions set forth below in this Article 8.

Section 8.02 Legal Defeasance and Discharge.

Upon the Issuer’s exercise under Section 8.01 hereof of the option applicable to this Section 8.02, the Issuer and each of the Guarantors will, subject to the satisfaction of the conditions set forth in Section 8.04 hereof, be deemed to have been discharged from their obligations with respect to all outstanding Notes of any series (including any Guarantees of such Notes) on the date the conditions set forth below are satisfied (hereinafter, “Legal Defeasance”). For this purpose, Legal Defeasance means that the Issuer and the Guarantors will be deemed to have paid and discharged the entire Indebtedness represented by the outstanding Notes of the applicable series (including any Guarantees of such Notes and the Security Documents with respect to such Notes and all Defaults and Events of Default cured), which will thereafter be deemed to be “outstanding” only for the purposes of Section 8.05 hereof and the other Sections of this Indenture referred to in clauses (a) and (b) below, and to have satisfied all their other obligations under such Notes, any Guarantees of such Notes the applicable Security Documents and this Indenture (and the Trustee, on demand of and at the expense of the Issuer, shall execute proper instruments acknowledging the same) and to have cured all then existing Defaults and Events of Default, except for the following provisions which will survive until otherwise terminated or discharged hereunder:

(a) the rights of Holders of outstanding Notes of such series to receive payments in respect of the principal of, premium on, if any, or interest, if any, on such Notes when such payments are due from the trust created pursuant to this Indenture referred to in Section 8.04 hereof;

(b) the Issuer’s obligations with respect to the Notes of such series under Article 2 and Section 4.02 hereof;

(c) the rights, powers, trusts, duties and immunities of the Trustee hereunder and the Issuer’s and the Guarantors’ obligations in connection therewith; and

(d) this Article 8.

Subject to compliance with this Article 8, the Issuer may exercise its option under this Section 8.02 notwithstanding the prior exercise of its option under Section 8.03 hereof.

 

129


Section 8.03 Covenant Defeasance.

Upon the Issuer’s exercise under Section 8.01 hereof of the option applicable to this Section 8.03 with respect to any series of Notes, the Issuer and each of the Guarantors will, subject to the satisfaction of the conditions set forth in Section 8.04 hereof, be released from each of their obligations under the covenants contained in Sections 3.09, 4.03, 4.04, 4.07, 4.08, 4.09, 4.10, 4.11, 4.12, 4.13, 4.15, 4.16 and 4.17 and clause (4) of Section 5.01 hereof with respect to the outstanding Notes of such series on and after the date the conditions set forth in Section 8.04 hereof are satisfied (hereinafter, “Covenant Defeasance”), and the Notes of such series will thereafter be deemed not “outstanding” for the purposes of any direction, waiver, consent or declaration or act of Holders (and the consequences of any thereof) in connection with such covenants, but will continue to be deemed “outstanding” for all other purposes hereunder (it being understood that such Notes will not be deemed outstanding for accounting purposes). For this purpose, Covenant Defeasance means that, with respect to the outstanding Notes of such series and any Guarantees of such Notes, the Issuer and the Guarantors may omit to comply with and will have no liability in respect of any term, condition or limitation set forth in any such covenant, whether directly or indirectly, by reason of any reference elsewhere herein to any such covenant or by reason of any reference in any such covenant to any other provision herein or in any other document and such omission to comply will not constitute a Default or an Event of Default under Section 6.01 hereof with respect to the applicable series of Notes, but, except as specified above, the remainder of this Indenture and such Notes and any Guarantees of such Notes will be unaffected thereby. In addition, upon the Issuer’s exercise under Section 8.01 hereof of the option applicable to this Section 8.03, subject to the satisfaction of the conditions set forth in Section 8.04 hereof, Sections 6.01(c), (d), (e), (f), (g) and (j) hereof will not constitute Events of Default with respect to the Notes of the applicable series.

Section 8.04 Conditions to Legal or Covenant Defeasance.

In order to exercise either Legal Defeasance or Covenant Defeasance under either Section 8.02 or 8.03 hereof:

(a) the Issuer must irrevocably deposit with the Trustee, in trust, for the benefit of the Holders of the applicable series of Notes, cash in U.S. dollars, non-callable Government Securities, or a combination thereof, in such amounts as will be sufficient, in the opinion of a nationally recognized investment bank, appraisal firm, or firm of independent public accountants, to pay the principal of, or interest and premium, if any, on the outstanding Notes of such series on the Stated Maturity or on the applicable redemption date, as the case may be, and the Issuer must specify whether the Notes of such series are being defeased to such Stated Maturity or to a particular redemption date;

(b) in the case of an election under Section 8.02 hereof, the Issuer shall deliver to the Trustee an Opinion of Counsel confirming that:

(1) the Issuer has received from, or there has been published by, the Internal Revenue Service a ruling; or

(2) since the Issue Date, there has been a change in the applicable federal income tax law,

 

130


in either case to the effect that, and based thereon such Opinion of Counsel shall confirm that, subject to customary assumptions and exclusions, the Holders of the outstanding Notes of such series will not recognize income, gain or loss for federal income tax purposes as a result of such Legal Defeasance and will be subject to federal income tax on the same amounts, in the same manner and at the same times as would have been the case if such Legal Defeasance had not occurred;

(c) in the case of an election under Section 8.03 hereof, the Issuer shall deliver to the Trustee an Opinion of Counsel confirming that, subject to customary assumptions and exclusions, the Holders of the outstanding Notes of such series will not recognize income, gain or loss for federal income tax purposes as a result of such Covenant Defeasance and will be subject to federal income tax on the same amounts, in the same manner and at the same times as would have been the case if such Covenant Defeasance had not occurred;

(d) no Event of Default with respect to the Notes of the applicable series shall have occurred and is continuing on the date of such deposit (other than an Event of Default resulting from the borrowing of funds to be applied to such deposit (and any similar and simultaneous deposit relating to other Indebtedness), and, in each case, the granting of Liens to secure such borrowings);

(e) such Legal Defeasance or Covenant Defeasance will not result in a breach or violation of, or constitute a default under, any material agreement or instrument (other than this Indenture and the agreements governing any other Indebtedness being defeased, discharged or replaced) to which the Issuer or any of its Subsidiaries is a party or by which the Issuer or any of its Subsidiaries is bound (other than an Event of Default resulting from the borrowing of funds to be applied to such deposit (and any similar and simultaneous deposit relating to other Indebtedness), and, in each case, the granting of Liens to secure such borrowings);

(f) the Issuer must deliver to the Trustee an Officer’s Certificate stating that the deposit was not made by the Issuer with the intent of preferring the Holders of Notes of the applicable series over the other creditors of the Issuer with the intent of defeating, hindering, delaying or defrauding any creditors of the Issuer or others; and

(g) the Issuer must deliver to the Trustee an Officer’s Certificate and an Opinion of Counsel, which Opinion of Counsel may be subject to customary assumptions and exclusions, each stating that all conditions precedent relating to the Legal Defeasance or the Covenant Defeasance have been complied with.

Section 8.05 Deposited Money and Government Securities to be Held in Trust; Other Miscellaneous Provisions.

Subject to Section 8.06 hereof, all money and non-callable Government Securities (including the proceeds thereof) deposited with the Trustee (or other qualifying trustee, collectively for purposes of this Section 8.05, the “Trustee”) pursuant to Section 8.04 hereof in respect of the outstanding Notes of any series will be held in trust and applied by the Trustee, in accordance with the provisions of such Notes of such series and this Indenture, to the payment, either directly or through any Paying Agent (including the Issuer acting as Paying Agent) as the Trustee may determine, to the Holders of such Notes of all sums due and to become due thereon in respect of principal, premium, if any, and interest, if any, but such money need not be segregated from other funds except to the extent required by law.

 

131


The Issuer will pay and indemnify the Trustee against any tax, fee or other charge imposed on or assessed against the cash or non-callable Government Securities deposited pursuant to Section 8.04 hereof or the principal and interest received in respect thereof other than any such tax, fee or other charge which by law is for the account of the Holders of the outstanding Notes of the applicable series.

Notwithstanding anything in this Article 8 to the contrary, the Trustee will deliver or pay to the Issuer from time to time upon the request of the Issuer any money or non-callable Government Securities held by it as provided in Section 8.04 hereof which, in the opinion of a nationally recognized firm of independent public accountants expressed in a written certification thereof delivered to the Trustee (which may be the opinion delivered under Section 8.04(a) hereof), are in excess of the amount thereof that would then be required to be deposited to effect an equivalent Legal Defeasance or Covenant Defeasance.

Section 8.06 Repayment to Issuer.

Any money deposited with the Trustee or any Paying Agent, or then held by the Issuer, in trust for the payment of the principal of, premium on, if any, or interest, if any, on any Note of a series and remaining unclaimed for two years after such principal, premium, if any, or interest, if any, has become due and payable shall be paid to the Issuer on its request or (if then held by the Issuer) will be discharged from such trust; and the Holder of such Note will thereafter be permitted to look only to the Issuer for payment thereof, and all liability of the Trustee or such Paying Agent with respect to such trust money, and all liability of the Issuer as trustee thereof, will thereupon cease; provided, however, that the Trustee or such Paying Agent, before being required to make any such repayment, may at the expense of the Issuer cause to be published once, in the New York Times and The Wall Street Journal (national edition), notice that such money remains unclaimed and that, after a date specified therein, which will not be less than 30 days from the date of such notification or publication, any unclaimed balance of such money then remaining will be repaid to the Issuer.

Section 8.07 Reinstatement.

If the Trustee or Paying Agent is unable to apply any U.S. dollars or non-callable Government Securities in accordance with Section 8.02 or 8.03 hereof, as the case may be, by reason of any order or judgment of any court or Governmental Authority enjoining, restraining or otherwise prohibiting such application, then the Issuer’s and the Guarantors’ obligations under this Indenture and the Notes of the applicable series and any Guarantees of such Notes will be revived and reinstated as though no deposit had occurred pursuant to Section 8.02 or 8.03 hereof until such time as the Trustee or Paying Agent is permitted to apply all such money in accordance with Section 8.02 or 8.03 hereof, as the case may be; provided, however, that, if the Issuer makes any payment of principal of, premium on, if any, interest, if any, on, any Note of such series following the reinstatement of its obligations, the Issuer will be subrogated to the rights of the Holders of such Notes to receive such payment from the money held by the Trustee or Paying Agent.

 

132


ARTICLE 9

AMENDMENT, SUPPLEMENT AND WAIVER

Section 9.01 Without Consent of Holders of Notes.

Notwithstanding Section 9.02 of this Indenture, without the consent of any Holder, the Issuer, the Guarantors, the Trustee and the Collateral Agent may amend or supplement this Indenture, the Notes, any Guarantee or any Security Document:

(a) to cure any ambiguity, mistake defect or inconsistency;

(b) to provide for uncertificated Notes in addition to or in place of certificated Notes;

(c) to provide for the assumption of the Issuer’s obligations to holders of Notes in the case of a merger or consolidation or sale of all or substantially all of the Issuer’s assets;

(d) to make any change that would provide any additional rights or benefits to the Holders or that does not adversely affect in any material respect the legal rights hereunder of any Holder;

(e) to comply with requirements of the Commission in connection with the qualification of this Indenture under the TIA to the extent this Indenture is to be so qualified;

(f) to add or modify covenants for the benefit of the Holders or to surrender any right or power conferred upon the Issuer or any Guarantor;

(g) to add a co-issuer or a Guarantor under this Indenture;

(h) to comply with the rules of any applicable securities depositary;

(i) to conform the text of this Indenture, the Notes, any Guarantee or any Security Document to any provision of the “Description of Notes” section of the Offering Memorandum, as set forth in an Officer’s Certificate to that effect;

(j) to evidence and provide for the acceptance and appointment under this Indenture or any Security Document of a successor Trustee, Collateral Agent or paying agent pursuant to the requirements hereof or thereof;

(k) to provide for or confirm the issuance of Additional Notes in accordance with this Indenture;

(l) to provide for any Guarantee with respect to the Notes or to effect the release of a Guarantor from any of its obligations under its Guarantee, this Indenture or the Security Documents to the extent permitted hereby or thereby;

(m) to provide for the issuance of exchange notes;

(n) to add customary provisions allowing for the issuance of new notes into escrow;

 

133


(o) to enter into any Applicable Intercreditor Agreement;

(p) to confirm or complete the grant of, secure, or expand the Collateral securing, or to add additional assets as Collateral to secure, the Notes and Guarantees;

(q) to confirm and evidence the release, termination or discharge of any Lien or security interest on the Collateral securing the Notes when permitted or required by this Indenture, or the Security Documents;

(r) in the case of any Security Document, to include therein any legend required to be set forth therein pursuant to any Applicable Intercreditor Agreements or to modify any such legend as required by any Applicable Intercreditor Agreements;

(s) to provide for the succession of any parties to the Security Documents (and other amendments that are administrative or ministerial in nature);

(t) in the case of the Collateral Agency Agreement, in order to subject the security interests in the Collateral in respect of any Additional First Lien Obligations to the terms of the Collateral Agency Agreement, in each case to the extent the incurrence of such Indebtedness, and the grant of all Liens on the Collateral held for the benefit of such Indebtedness were not prohibited under this Indenture; or

(u) with respect to any Security Document, to the extent such amendment is reasonably necessary to comply with the terms of the Collateral Agency Agreement.

Upon the request of the Issuer, and upon receipt by the Trustee and the Collateral Agent of the documents described in Sections 7.02 and 9.05 hereof (as applicable), the Trustee and the Collateral Agent will join with the Issuer (and, with respect to an amended or supplemental indenture for the addition of a new Guarantor pursuant to this Indenture, such new Guarantor) in the execution of any amended or supplemental indenture authorized or permitted by the terms of this Indenture and to make any further appropriate agreements and stipulations that may be therein contained, but neither the Trustee nor the Collateral Agent will be obligated to enter into such amended or supplemental indenture that affects its own rights, duties or immunities under this Indenture or otherwise.

Section 9.02 With Consent of Holders of Notes.

Except as provided below in this Section 9.02, the Issuer, the Guarantors, the Trustee and the Collateral Agent may amend or supplement this Indenture (including, without limitation, Section 3.09, 4.10 and 4.15 hereof) and the Notes, any Guarantee or the Security Documents with the consent of the Holders of at least a majority in aggregate principal amount of the then outstanding Notes (including, without limitation, Additional Notes, if any) voting as a single class (including, without limitation, consents obtained in connection with a tender offer or exchange offer for, or purchase of, any Notes), and, subject to Sections 6.04 and 6.07 hereof, any existing Default (other than a Default on the payment of the principal of, premium on, if any, or interest, if any, on, the Notes, except a payment default resulting from an acceleration that has been rescinded) or compliance with any provision of this Indenture, the Notes any Guarantees, the Security Documents or any Applicable Intercreditor Agreement may be waived with the consent of the

 

134


Holders of a majority in aggregate principal amount of the then outstanding Notes (including, without limitation, Additional Notes, if any) voting as a single class (including, without limitation, consents obtained in connection with a tender offer or exchange offer for, or purchase of, any Notes), provided that (x) if any such amendment or waiver will only affect one series of Notes (or less than all series of Notes) then outstanding under this Indenture, then only the consent of the holders of a majority in principal amount of the Notes of such series then outstanding (including, in each case, consents obtained in connection with a purchase of, or tender offer or exchange offer for, any such Notes) shall be required and (y) if any such amendment or waiver by its terms will affect a series of Notes in a manner different and materially adverse relative to the manner such amendment or waiver affects other series of Notes, then the consent of the holders of a majority in principal amount of the Notes of each such series then outstanding (including, in each case, consents obtained in connection with a purchase of, or tender offer or exchange offer for, any such Notes) shall be required. Section 2.08 hereof shall determine which Notes are considered to be “outstanding” for purposes of this Section 9.02.

Upon the request of the Issuer accompanied by a resolution of its Board of Directors authorizing the execution of any such amended or supplemental indenture, and upon the filing with the Trustee and the Collateral Agent of evidence satisfactory to each of the Trustee and the Collateral Agent of the consent of the Holders of Notes as aforesaid, and upon receipt by the Trustee and the Collateral Agent of the documents described in Sections 7.02 and 9.05 hereof (as applicable), the Trustee and the Collateral Agent will join with the Issuer and solely to the extent applicable, the Guarantors, in the execution of such amended or supplemental indenture unless such amended or supplemental indenture directly affects the Trustee’s or the Collateral Agent’s own rights, duties or immunities under this Indenture or otherwise, in which case the Trustee or the Collateral Agent may in its discretion, but will not be obligated to, enter into such amended or supplemental Indenture.

It is not necessary for the consent of the Holders of Notes under this Section 9.02 to approve the particular form of any proposed amendment, supplement or waiver, but it is sufficient if such consent approves the substance thereof.

After an amendment, supplement or waiver under this Section 9.02 becomes effective, the Issuer will transmit in accordance with the Applicable Procedures to the Holders of Notes affected thereby a notice briefly describing the amendment, supplement or waiver. Any failure of the Issuer to mail or transmit such notice, or any defect therein, will not, however, in any way impair or affect the validity of any such amended or supplemental indenture or waiver. Subject to Section 6.04 hereof, the Holders of a majority in aggregate principal amount of the Notes of any series then outstanding voting as a single class may waive compliance in a particular instance by the Issuer with any provision of this Indenture, the Notes, the Guarantees or the Security Documents with respect to such series of Notes. However, without the consent of each affected Holder, an amendment, supplement or waiver under this Section 9.02 may not (with respect to any Notes held by a non-consenting Holder):

(a) reduce the principal amount of Notes whose Holders must consent to an amendment, supplement or waiver;

 

135


(b) reduce the principal of or change the stated final maturity of any such Note or alter or waive the provisions with respect to the redemption of such Notes (other than provisions relating to (a) notice periods for redemption and conditions to redemption and (b) as provided above with respect to Sections 3.09, 4.10 and 4.15 hereof);

(c) reduce the rate of or change the time for payment of interest on any such Note;

(d) waive a Default or Event of Default in the payment of principal of, premium on, if any, or interest, if any, on, such Notes (except a rescission of acceleration of such Notes by the Holders of at least a majority in aggregate principal amount of the then outstanding Notes and a waiver of the payment default that resulted from such acceleration);

(e) make any such Note payable in currency other than that stated in such Notes;

(f) make any change in the provisions of this Indenture relating to waivers of past Defaults or the rights of Holders of such Notes to receive payments of principal of, premium, if any, on, or interest, if any, on such Notes; or

(g) make any change in the preceding amendment and waiver provisions.

Furthermore, without the consent of the Holders of at least two-thirds in aggregate principal amount of the Notes then outstanding voting as one class, an amendment or waiver may not (A) make any change in any Security Document or the provisions in this Indenture relating to the Collateral or the Security Documents or the application of trust proceeds of the Collateral in any case that would release all or substantially all of the Collateral from the Liens of the Security Documents, or (B) change or alter the priority of the Liens securing Obligations in respect of the Notes in any way materially adverse, taken as a whole, to the holders of the Notes, in each case except as permitted by the terms of this Indenture or the Security Documents.

For the avoidance of doubt, no amendment to, or deletion of any of the covenants set forth in Article 4 or action taken in compliance with the covenants in effect at the time of such action, shall be deemed to impair or affect any legal rights of any Holders to receive payment of principal of or premium, if any, or interest on the Notes or to institute suit for the enforcement of any payment on or with respect to such Holder’s Notes.

Section 9.03 Revocation and Effect of Consents.

Until an amendment, supplement or waiver becomes effective, a consent to it by a Holder is a continuing consent by the Holder and every subsequent Holder of a Note or portion of a Note that evidences the same debt as the consenting Holder’s Note, even if notation of the consent is not made on any Note. However, any such Holder or subsequent Holder may revoke the consent as to its Note if the Trustee receives written notice of revocation before the date the amendment, supplement or waiver becomes effective. An amendment, supplement or waiver becomes effective in accordance with its terms and thereafter binds every Holder.

 

136


Section 9.04 Notation on or Exchange of Notes.

The Trustee may place an appropriate notation about an amendment, supplement or waiver on any Note thereafter authenticated. The Issuer in exchange for all Notes may issue and the Trustee shall, upon receipt of an Authentication Order, authenticate new Notes that reflect the amendment, supplement or waiver.

Failure to make the appropriate notation or issue a new Note will not affect the validity and effect of such amendment, supplement or waiver.

Section 9.05 Trustee to Sign Amendments, etc.

The Trustee and the Collateral Agent shall sign any amendment, supplement or waiver authorized pursuant to this Article 9 if the amendment, supplement or wavier does not adversely affect the rights, duties, liabilities or immunities of the Trustee or the Collateral Agent, as applicable. The Issuer may not sign an amendment, supplement or waiver until the Board of Directors of the Issuer approves it. In executing any amendment, supplement or waiver, the Trustee and the Collateral Agent shall be provided with and (subject to Section 7.01 hereof) shall be fully protected in relying upon, in addition to the documents required by Section 12.02 hereof, an Officer’s Certificate and an Opinion of Counsel each stating that the execution of such amended or supplemental indenture or security documents or intercreditor agreements, or waiver, is authorized or permitted by this Indenture.

ARTICLE 10

GUARANTEES

Section 10.01 Guarantee.

(a) Subject to this Article 10, each of the Guarantors hereby, jointly and severally, unconditionally guarantees to each Holder and to the Trustee and its successors and assigns, irrespective of the validity and enforceability of this Indenture, the Notes or the obligations of the Issuer hereunder or thereunder, that:

(1) the principal of, premium, if any, on, and interest, if any, on the Notes of the applicable series will be promptly paid in full when due, whether at maturity, by acceleration, redemption or otherwise, and interest on the overdue principal of, premium on, if any, interest, if any, on, the Notes of such series, if lawful, and all other obligations of the Issuer to the Holders or the Trustee hereunder or thereunder will be promptly paid in full or performed, all in accordance with the terms hereof and thereof; and

(2) in case of any extension of time of payment or renewal of any Notes of a series or any of such other obligations, that same will be promptly paid in full when due or performed in accordance with the terms of the extension or renewal, whether at stated maturity, by acceleration or otherwise.

Failing payment when due of any amount so guaranteed or any performance so guaranteed for whatever reason, the Guarantors will be jointly and severally obligated to pay the same immediately. Each Guarantor agrees that this is a guarantee of payment and not a guarantee of collection.

 

137


(b) The Guarantors hereby agree that their obligations hereunder are unconditional, irrespective of the validity, regularity or enforceability of the Notes or this Indenture, the absence of any action to enforce the same, any waiver or consent by any Holder with respect to any provisions hereof or thereof, the recovery of any judgment against the Issuer, any action to enforce the same or any other circumstance which might otherwise constitute a legal or equitable discharge or defense of a guarantor. Each Guarantor hereby waives diligence, presentment, demand of payment, filing of claims with a court in the event of insolvency or bankruptcy of the Issuer, any right to require a proceeding first against the Issuer, protest, notice and all demands whatsoever and covenant that this Guarantee will not be discharged except by complete performance of the obligations contained in the Notes and this Indenture.

(c) If any Holder or the Trustee is required by any court or otherwise to return to the Issuer, the Guarantors or any custodian, trustee, liquidator or other similar official acting in relation to either the Issuer or the Guarantors, any amount paid by either to the Trustee or such Holder, this Guarantee, to the extent theretofore discharged, will be reinstated in full force and effect.

(d) Each Guarantor agrees that it will not be entitled to any right of subrogation in relation to the Holders in respect of any obligations guaranteed hereby until payment in full of all obligations guaranteed hereby. Each Guarantor further agrees that, as between the Guarantors, on the one hand, and the Holders and the Trustee, on the other hand, (1) the maturity of the obligations guaranteed hereby may be accelerated as provided in Article 6 hereof for the purposes of this Guarantee, notwithstanding any stay, injunction or other prohibition preventing such acceleration in respect of the obligations guaranteed hereby, and (2) in the event of any declaration of acceleration of such obligations as provided in Article 6 hereof, such obligations (whether or not due and payable) will forthwith become due and payable by the Guarantors for the purpose of this Guarantee. The Guarantors will have the right to seek contribution from any non-paying Guarantor so long as the exercise of such right does not impair the rights of the Holders under the Guarantee.

Section 10.02 Limitation on Guarantor Liability.

Each Guarantor, and by its acceptance of Notes, each Holder, hereby confirms that it is the intention of all such parties that the Guarantee of such Guarantor not constitute a fraudulent transfer or conveyance for purposes of Bankruptcy Law, the Uniform Fraudulent Conveyance Act, the Uniform Fraudulent Transfer Act or any similar federal or state law to the extent applicable to any Guarantee. To effectuate the foregoing intention, the Trustee, the Holders and the Guarantors hereby irrevocably agree that the obligations of such Guarantor will be limited to the maximum amount that will, after giving effect to such maximum amount and all other contingent and fixed liabilities of such Guarantor that are relevant under such laws, and after giving effect to any collections from, rights to receive contribution from or payments made by or on behalf of any other Guarantor in respect of the obligations of such other Guarantor under this Article 10, result in the obligations of such Guarantor under its Guarantee not constituting a fraudulent transfer or conveyance.

 

138


Section 10.03 Execution and Delivery of Guarantee.

To evidence its Guarantee set forth in Section 10.01 hereof, each Guarantor hereby agrees that this Indenture or, if applicable, a Supplemental Indenture substantially in the form of Exhibit E, shall be executed on behalf of such Guarantor by an Officer of such Guarantor.

If an Officer whose signature is on this Indenture no longer holds that office at the time the Trustee authenticates the Note, the Guarantee will be valid nevertheless.

The delivery of any Note by the Trustee, after the authentication thereof hereunder, will constitute due delivery of the Guarantee set forth in this Indenture on behalf of the Guarantors.

Section 10.04 Releases.

The Guarantee of a Guarantor will be released and discharged automatically and unconditionally:

(a) upon the sale, disposition, exchange or other transfer (including through merger, consolidation or otherwise) of the Capital Stock of the Guarantor, after which such Guarantor is no longer a Restricted Subsidiary, or all or substantially all of the assets of such Guarantor (other than to the Issuer or a Restricted Subsidiary) if such sale, disposition, exchange or other transfer is not prohibited by this Indenture, and the release is otherwise not prohibited by this Indenture;

(b) upon the liquidation, winding up or dissolution of such Guarantor or the merger or consolidation of such Guarantor with and into the Issuer or another Guarantor in accordance with the applicable provisions of this Indenture;

(c) following delivery at any time by the Issuer to the Trustee of an Officer’s Certificate to the effect that the aggregate amount of Indebtedness for borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit then outstanding of such Guarantor (other than any such Indebtedness owed to the Issuer or any Guarantor) does not exceed $250.0 million (excluding the Notes, and excluding any other Indebtedness that will be released or discharged with respect to such Guarantor substantially concurrently with any release pursuant to this clause (c)); provided that such Guarantee will be reinstated if and to the extent required under Section 4.16 subsequent to such release;

(d) upon Legal Defeasance or satisfaction and discharge of the Notes as provided in Section 8.02 and Article 11;

(e) upon the occurrence of a Covenant Suspension Event, provided that if, after any Covenant Suspension Event, a Reversion Date shall occur, then the Suspension Period with respect to such Covenant Suspension Event shall terminate and all actions reasonably necessary to provide that the Notes shall have been unconditionally guaranteed by such Guarantor (if and to the extent such guarantee is required pursuant to Section 4.16) shall be taken within 90 days after such Reversion Date or as soon as reasonably practicable thereafter;

(f) upon the occurrence of any event after which such Guarantor is no longer a Restricted Subsidiary;

 

139


(g) if the Issuer designates such Guarantor as an Unrestricted Subsidiary in accordance with the applicable provisions of this Indenture; or

(h) as set forth in Article 9 or in accordance with the provisions of any Applicable Intercreditor Agreement then in effect with respect to the Notes.

The Trustee shall not be required to execute any document or give any confirmation as to or otherwise evidence any release or discharge of any Guarantee unless and until (1) requested in writing to do so by the Issuer and (2) the Issuer delivers an Officer’s Certificate and an Opinion of Counsel to the Trustee stating that all conditions precedent to the release and discharge of the Guarantee have been satisfied.

ARTICLE 11

SATISFACTION AND DISCHARGE

Section 11.01 Satisfaction and Discharge.

This Indenture will be discharged and will cease to be of further effect as to all Notes of any series issued hereunder, when:

(a) either:

(1) all Notes of the applicable series that have been authenticated, except lost, stolen or destroyed Notes of such series that have been replaced or paid and Notes of such series for whose payment money has been deposited in trust or segregated and held in trust by the Issuer and thereafter repaid to the Issuer, have been delivered to the Trustee for cancellation; or

(2) all Notes of the applicable series that have not been delivered to the Trustee for cancellation have become due and payable by reason of the mailing or transmitting of a notice of redemption or otherwise or will become due and payable within one year or are to be called for redemption within one year under irrevocable arrangements for the giving of notice of redemption by the Trustee in the name, and at the expense, of the Issuer, and the Issuer or any Guarantor has irrevocably deposited or caused to be deposited with the Trustee as trust funds in trust solely for the benefit of the Holders of the Notes of such series, cash in U.S. dollars, non-callable Government Securities, or a combination thereof, in such amounts as will be sufficient, without consideration of any reinvestment of interest, to pay and discharge the entire Indebtedness on the Notes of the applicable series not delivered to the Trustee for cancellation for principal, premium, if any, and interest, if any, to the date of maturity or redemption;

(b) in respect of subclause (2) of clause (a) of this Section 11.01, no Event of Default with respect to the applicable series of Notes has occurred and is continuing on the date of the deposit (other than an Event of Default resulting from the borrowing of funds to be applied to such deposit and any similar and simultaneous deposit relating to other Indebtedness and, in each case, the granting of Liens to secure such borrowings) and the deposit will not result in a breach or violation of, or constitute a default under, any other instrument to which the Issuer or any

 

140


Guarantor is a party or by which the Issuer or any Guarantor is bound (other than with respect to the borrowing of funds to be applied concurrently to make the deposit required to effect such satisfaction and discharge and any similar concurrent deposit relating to other Indebtedness, and in each case the granting of Liens to secure such borrowings);

(c) the Issuer or any Guarantor has paid or caused to be paid all sums payable by it under this Indenture with respect to the Notes of the applicable series; and

(d) the Issuer has delivered irrevocable written instructions to the Trustee under this Indenture to apply the deposited money toward the payment of the Notes of the applicable series at maturity or on the redemption date, as the case may be.

In addition, the Issuer must deliver an Officer’s Certificate and an Opinion of Counsel to the Trustee to the effect that all conditions precedent to satisfaction and discharge of the Notes of the applicable series have been complied with.

Notwithstanding the satisfaction and discharge of this Indenture, if money has been deposited with the Trustee pursuant to subclause (2) of clause (a) of this Section 11.01, the provisions of Sections 11.02 and 8.06 hereof will survive. In addition, nothing in this Section 11.01 will be deemed to discharge those provisions of Section 7.07 hereof, that, by their terms, survive the satisfaction and discharge of this Indenture.

Section 11.02 Application of Trust Money.

Subject to the provisions of Section 8.06 hereof, all money deposited with the Trustee pursuant to Section 11.01 hereof shall be held in trust and applied by it, in accordance with the provisions of the Notes of the applicable series and this Indenture, to the payment, either directly or through any Paying Agent (including the Issuer acting as its own Paying Agent) as the Trustee may determine, to the Persons entitled thereto, of the principal, premium, if any, interest, if any, for whose payment such money has been deposited with the Trustee; but such money need not be segregated from other funds except to the extent required by law.

If the Trustee or Paying Agent is unable to apply any money or Government Securities in accordance with Section 11.01 hereof by reason of any legal proceeding or by reason of any order or judgment of any court or Governmental Authority enjoining, restraining or otherwise prohibiting such application, the Issuer’s and any Guarantor’s obligations under this Indenture and the Notes of the applicable series shall be revived and reinstated as though no deposit had occurred pursuant to Section 11.01 hereof; provided that if the Issuer has made any payment of principal of, premium on, if any, or interest, if any, on, any Notes of such series because of the reinstatement of its obligations, the Issuer shall be subrogated to the rights of the Holders of such Notes to receive such payment from the money or Government Securities held by the Trustee or Paying Agent.

 

141


ARTICLE 12

COLLATERAL AND SECURITY

Section 12.01 General.

The Notes are, and any Guarantees will be, secured on a first-priority basis (subject to permitted encumbrances) by Liens on the Collateral, other than, in each case, during any Suspension Period with respect to a series of Notes. The Liens securing the Notes and the Guarantees will be shared equally and ratably (subject to Liens permitted to be incurred under Section 4.12) with the holders of other First Lien Obligations.

Section 12.02 Security Documents.

(a) In order to secure the due and punctual payment of the Note Obligations, when the same shall be due and payable, whether on an Interest Payment Date, at maturity, by acceleration, repurchase, redemption or otherwise, and interest on the overdue principal of and interest (to the extent permitted by law) on the Notes and performance of all other Note Obligations, (i) the Issuer and the Guarantors, if any, have prior to the Issue Date, entered into Security Documents granting the Collateral Agent a Lien on (A) substantially all the existing and future tangible and intangible assets and rights of the Issuer and the Guarantors, if any (other than, in each case, Excluded Assets) and (B) Equity Interests in all direct Subsidiaries of the Issuer and each Guarantor, if any (other than, in each case, Excluded Capital Stock), and (ii) the Issuer agrees that it shall take all such action as shall be required to ensure that the Note Obligations will (other than, in each case, during any Suspension Period with respect to a series of Notes) be secured by a Lien, subject only to Permitted Liens, on the Collateral.

(b) To the extent, but only to the extent, permitted hereby, the Issuer and the Guarantors may incur Additional First Lien Obligations. Any additional class or series of Additional First Lien Obligations will be secured by Liens on the Collateral that rank pari passu with the Liens securing First Lien Obligations, in each case, under and pursuant to the Security Documents, once the Senior Class Debt Representative with respect to any such class or series of Additional First Lien Obligations, acting on behalf of the holders of such series of Additional First Lien Obligations, (1) becomes a party to the First Lien Intercreditor Agreement by satisfying the conditions set forth therein and (2) becomes a party to the Collateral Agency Agreement.

(c) If the Issuer or any of the Guarantors incurs Additional First Lien Obligations, the Collateral Agent, on behalf of itself, the other Senior Class Debt Representatives, acting on behalf of the holders of the applicable series of Additional First Lien Obligations, and the other agents (if any) will, as applicable, enter into a joinder to the First Lien Intercreditor Agreement substantially in the form of Exhibit A-1 thereto.

(d) If the Issuer or any of the Guarantors incurs Indebtedness secured by a Lien on the Collateral that is junior in priority relative to the Liens on the Collateral securing the First Lien Obligations, the Issuer, the Guarantors, the Collateral Agent, acting on behalf of itself, the Trustee, acting on behalf of the Holders of the Notes, the other collateral agents (if any) and the applicable Junior Lien Representative, on behalf of itself and the applicable Junior Lien Secured Parties, will

 

142


enter into a junior lien intercreditor agreement, substantially in the form attached hereto as Exhibit F or which otherwise constitutes a junior lien intercreditor agreement that is an Applicable Intercreditor Agreement (any such junior lien intercreditor agreement, the “Junior Lien Intercreditor Agreement”).

(e) The Note Documents (other than any Applicable Intercreditor Agreement) will be subject to the terms, limitations and conditions set forth in each Applicable Intercreditor Agreement. Each Holder of Notes, by its acceptance of a Note, is deemed to (i) have consented and agreed to the terms of each Security Document (including the First Lien Intercreditor Agreement and each other Applicable Intercreditor Agreement, if any, entered into after the Issue Date in accordance with clause (d) of this Section 12.02), as originally in effect and as amended, supplemented or replaced from time to time in accordance with its terms or the terms of this Indenture, the First Lien Intercreditor Agreement or, if applicable, each Applicable Intercreditor Agreement, (ii) have authorized and directed the Trustee to enter into or execute a joinder with respect to (A) the Collateral Agency Agreement on the Issue Date, (B) the First Lien Intercreditor Agreement on the Issue Date and (C) each other Applicable Intercreditor Agreement at any time after the Issue Date in accordance with clause (d) of this Section 12.02, (iii) have consented to the appointment of the Collateral Agent pursuant to the Collateral Agency Agreement, (iv) have authorized and directed the Collateral Agent to enter into the Security Documents to which it is, or is intended to be, a party, and (v) have authorized and empowered the Collateral Agent (through the Collateral Agency Agreement, the First Lien Intercreditor Agreement and each other Applicable Intercreditor Agreement, if any) to bind the Holders of Notes as set forth in the Security Documents to which they are a party and to perform its obligations and exercise its rights and powers thereunder, including entering into amendments permitted by the terms of the Note Documents. To the extent that any provision of the Note Documents is not consistent with or contradicts the Collateral Agency Agreement (or the First Lien Intercreditor Agreement or Applicable Intercreditor Agreements (if any)), the Collateral Agency Agreement, the First Lien Intercreditor Agreement and/or the other Applicable Intercreditor Agreements (if any) shall govern.

(f) Each Holder of Notes, by its acceptance of a Note, is deemed to have:

(1) authorized, consented to and directed the Trustee to enter into and join the Collateral Agency Agreement, including by its execution of applicable joinder documentation in its capacity as “New Senior Class Debt Representative” (as defined in the Collateral Agency Agreement) in respect of the Note Obligations;

(2) other than during any Suspension Period, agreed (in its capacity as a Holder of Notes) that it is subject to and bound by the provisions of the Collateral Agency Agreement, each Security Document, the First Lien Intercreditor Agreement and each other Applicable Intercreditor Agreement in effect at any time;

(3) ratified the Collateral Agent’s execution and delivery of the Security Documents prior to the date hereof (in accordance with the Collateral Agency Agreement);

 

143


(4) consented and agreed that the Collateral Agent may execute and deliver any additional Security Documents (including any Applicable Intercreditor Agreement) not in effect as of the date hereof and act in accordance with the terms thereof;

(5) subject to the terms of any Applicable Intercreditor Agreement, consented and agreed that the Collateral Agent may, in its sole discretion and without the consent of the Trustee or the Holders, take all actions it deems necessary or appropriate in order to:

(A) enforce any of the terms of the Security Documents; and

(B) collect and receive any and all amounts payable in respect of the Note Obligations of the Issuer and the Guarantors to the Holders, the Collateral Agent or the Trustee under the Note Documents.

Section 12.03 Recording, Registration and Opinions; Trustees Disclaimer Regarding Collateral.

(a) Unless the Collateral has been released (including during a Suspension Period), the Issuer and, if applicable, any Guarantors, shall take or cause to be taken all actions required pursuant to the terms of the Security Documents to perfect, maintain, preserve and protect the Lien on the Collateral granted by the Collateral Documents (subject only to Permitted Liens and to the terms of the Security Documents), including without limitation arranging for the filing of financing statements, continuation statements and any instruments of further assurance, in such manner and in such places as may be required by law fully to preserve and protect the rights of the Holders, the Trustee and the Collateral Agent under the Note Documents to all property now or hereafter at any time comprising the Collateral. The Issuer shall from time to time promptly pay all financing, continuation statements, registration and/or filing fees, charges and taxes relating to the Note Documents, any amendments thereto and any other instruments of further assurance required hereunder or pursuant to the Collateral Documents. Neither the Trustee nor the Collateral Agent shall have any obligation to, and neither of them shall be responsible for any failure to, so register, file or record.

(b) [Reserved.]

(c) Notwithstanding anything to the contrary set forth in the Note Documents, neither the Trustee nor the Collateral Agent shall be responsible for the existence, genuineness or value of any of the Collateral, or for the creation, validity, perfection, priority or enforceability of the Liens in any of the Collateral, whether impaired by operation of law or by reason of any action or omission to act on its part hereunder, for the validity or sufficiency of the Collateral or any agreement or assignment contained therein, for the validity of the title of the Issuer to the Collateral, for insuring the Collateral or for the payment of taxes, charges, assessments or Liens upon the Collateral or otherwise as to the maintenance of the Collateral.

(d) The Trustee shall have no duty to ascertain or inquire as to the performance or observance of any of the terms of this Indenture or any Security Document by the Issuer, any Guarantor or any other Person that is a party thereto or bound thereby. The Trustee shall not be responsible or liable for seeing to or monitoring the attachment, perfection, or priority of any lien or security interest created or intended to be created in the Collateral hereby or by any of the

 

144


Security Documents. The Trustee shall not be responsible for the preparation, correctness, filing, re-filing, recording or re-recording of any security documents or instruments, including UCC financing statements or continuation statements in any public office at any time or times or otherwise perfecting or maintaining the perfection of any lien or security interest in any of the Collateral.

Section 12.04 Possession, Use and Release of Collateral.

(a) Each Holder, by accepting a Note, consents and agrees to the provisions of the Note Documents governing the possession, use and release of Collateral. Each Holder, by accepting a Note, consents and agrees that Collateral may, and, as applicable, shall, be released or substituted in accordance with the terms of the Security Documents.

(b) The Liens on the Collateral in favor of the Collateral Agent with respect to all Note Obligations of the Issuer and the Guarantors secured by such Collateral will be released automatically and unconditionally:

(1) upon payment in full of all outstanding Notes and all other amounts due under this Indenture (including any Guarantee), the Collateral Agency Agreement and the Notes;

(2) upon legal defeasance or satisfaction and discharge of the Notes as set forth under Articles 8 and 11, respectively;

(3) as to any Collateral that constitutes all or substantially all of the Collateral, with the consent of the holders of at least two-thirds in principal amount of the Notes then outstanding;

(4) to enable the Issuer and/or any Guarantor to consummate the disposition of property or assets to a Person other than the Issuer or a Guarantor (unless such property or other assets transferred to a Person that is the Issuer or a Guarantor are automatically, substantially concurrently with or in advance of such release, the subject of Liens granted by such transferee securing the Notes) to the extent not prohibited under Section 4.10;

(5) in the case of a sale or other transfer as part of or in connection with an Asset Sale by the Issuer or any Guarantor to a Person other than the Issuer or a Guarantor (unless such property or other assets transferred to a Person that is the Issuer or a Guarantor are automatically, substantially concurrently with or in advance of such release, the subject of Liens granted by such transferee securing the Notes) in a transaction permitted hereunder;

(6) with respect to any Collateral owned by a Guarantor whose Capital Stock is sold or otherwise disposed of in accordance with the terms of this Indenture to a Person that is not (either before or after giving effect to such transaction) the Issuer or a Restricted Subsidiary, upon such sale or other disposition;

 

145


(7) upon the occurrence of a Covenant Suspension Event, provided that, if, after any Covenant Suspension Event, a Reversion Date shall occur, then the Suspension Period with respect to such Covenant Suspension Event shall terminate and the Issuer will take all actions reasonably necessary to provide that the Notes and any Guarantees shall be secured on a first-priority basis (subject to permitted encumbrances) by Liens on the Collateral within 120 days after such Reversion Date or as soon as reasonably practicable thereafter (but in each case, subject to all limitations and exclusions set forth herein and in the Security Documents);

(8) with respect to property or other assets owned by a Guarantor that is released from its Guarantee pursuant to the terms of this Indenture, concurrently upon the release from such Guarantee;

(9) with respect to property or other assets that does not constitute Collateral (or ceases to constitute Collateral) (including by being or becoming an Excluded Asset); and

(10) as required by the terms of any Applicable Intercreditor Agreement (including if consent to release all Liens on Collateral has been given by the Majority Agent, acting in accordance with the First Lien Financing Document(s) for the series of First Lien Obligations with respect to which it is acting in such capacity, pursuant to the First Lien Intercreditor Agreement).

(c) At the request of the Issuer, and upon delivery of an Officer’s Certificate and Opinion of Counsel delivered to the Trustee in accordance with in the requirements specified in this Indenture, the Trustee will execute and deliver any documents, instructions or instruments evidencing the consent of the Holders (and the Holders will be deemed to have consented to and authorized the Trustee to execute and deliver any such documentation, instructions or instruments) to any permitted release contemplated by Section 12.04(b). Each Holder of Notes, by its acceptance of a Note, is deemed to have irrevocably consented to and authorized the Trustee and the Collateral Agent to execute and deliver any such documentation, instructions or instruments relating to any such permitted release under this Indenture or the Security Documents.

(d) The Collateral Agent or the Trustee, as applicable, shall execute and deliver all such authorizations, instructions and other instruments and take such actions (and the Holders will be deemed to have consented to and authorized the Collateral Agent or the Trustee, as applicable, to execute and deliver any such authorization, instruction or instrument and take any such action) under the Security Documents or otherwise as may be reasonably requested in writing by the Issuer, at the cost of the Issuer, to evidence, confirm and effectuate any release of Collateral provided for in Section 12.04(b); provided that the Trustee and the Collateral Agent shall be entitled to receive an Opinion of Counsel and an Officer’s Certificate in connection with any such request of the Issuer related to the release of any Collateral.

Section 12.05 Suits to Protect the Collateral

Subject to the provisions of Article 7 and the Security Documents, the Trustee may or may direct the Collateral Agent to take all actions it determines in order to:

(a) enforce any of the terms of the Security Documents; and

 

146


(b) collect and receive any and all amounts payable in respect of the Obligations hereunder.

Subject to the provisions of the Security Documents, the Trustee and the Collateral Agent shall have power to institute and to maintain such suits and proceedings as the Trustee or the Collateral Agent may determine to prevent any impairment of the Collateral by any acts which may be unlawful or in violation of any of the Security Documents or this Indenture, and such suits and proceedings as the Trustee or the Collateral Agent may determine to preserve or protect its interests and the interests of the Holders in the Collateral. Nothing in this Section 12.05 shall be considered to impose any such duty or obligation to act on the part of the Trustee or the Collateral Agent.

Section 12.06 Authorization of Receipt of Funds by the Trustee Under the Security Documents.

Subject to the provisions of any Applicable Intercreditor Agreement, the Trustee is authorized to receive any funds for the Notes Parties distributed under the Security Documents, and to make further distributions of such funds to the Holders according to the provisions of this Indenture.

Section 12.07 Purchaser Protected.

No purchaser or grantee of any property or rights purporting to be released herefrom shall be bound to ascertain the authority of the Trustee or the Collateral Agent to execute the release or to inquire as to the existence of any conditions herein prescribed for the exercise of such authority; nor shall any purchaser or grantee of any property or rights permitted by this Indenture to be sold or otherwise disposed of by the Issuer or any Guarantor be under any obligation to ascertain or inquire into the authority of the Issuer or such Guarantor to make such sale or other disposition.

ARTICLE 13

MISCELLANEOUS

Section 13.01 Notices.

Any notice or communication by the Issuer, any Guarantor or the Trustee to the others is duly given if in writing and delivered in Person or by first class mail (registered or certified, return receipt requested), facsimile transmission, electronic mail or overnight air courier guaranteeing next day delivery, to the others’ address:

If to the Issuer and/or any Guarantor:

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

E-mail: [***]

Attention: Chief Financial Officer and General Counsel

 

147


With a copy to:

Davis Polk & Wardwell LLP

450 Lexington Avenue

New York, NY 10017

E-mail: [***]

Attention: [***]

If to the Trustee:

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Facsimile No.: [***]

E-mail: [***]

Attention: Corporate Trust Administration

The Issuer, any Guarantor or the Trustee, by notice to the others, may designate additional or different addresses for subsequent notices or communications.

All notices and communications (other than those sent to Holders) will be deemed to have been duly given: at the time delivered by hand, if personally delivered; five Business Days after being deposited in the mail, postage prepaid, if mailed; when receipt acknowledged, if transmitted by facsimile; at the time sent, if transmitted by electronic mail; and the next Business Day after timely delivery to the courier, if sent by overnight air courier guaranteeing next day delivery; provided that all notices and communications to the Trustee shall not be deemed received by the Trustee unless actually received by the Trustee at its address, facsimile number or electronic mail address set forth above.

Any notice or communication to a Holder will be mailed by first class mail, or by certified or registered mail, return receipt requested, or by overnight air courier guaranteeing next day delivery to its address shown on the register kept by the Registrar. Failure to mail a notice or communication to a Holder or any defect in it will not affect its sufficiency with respect to other Holders.

If a notice or communication is mailed in the manner provided above within the time prescribed, it is duly given, whether or not the addressee receives it.

If the Issuer mails a notice or communication to Holders, it will send a copy to the Trustee and each Agent at the same time by any of the means described above with respect to notice or communication by the Issuer.

 

148


Section 13.02 Certificate and Opinion as to Conditions Precedent.

Upon any request or application by the Issuer to the Trustee to take any action under any Note Document, the Issuer shall furnish to the Trustee:

(1) an Officer’s Certificate in form reasonably satisfactory to the Trustee (which must include the statements set forth in Section 13.03) stating that, in the opinion of the signers, all conditions precedent and covenants, if any, provided for in the relevant Note Document(s) relating to the proposed action have been complied with; and

(2) an Opinion of Counsel in form reasonably satisfactory to the Trustee (which must include the statements set forth in Section 13.03) stating that, in the opinion of such counsel, all such conditions precedent and covenants have been complied with, provided, that no such Opinion of Counsel shall be delivered on the date of this Indenture in connection with the original issuance of the initial Global Notes.

The Trustee shall, to the extent permitted by Sections 7.01 and 7.02, be entitled to rely upon, as conclusive evidence of compliance with the foregoing provisions the appropriate statements contained in such documents and such Opinion of Counsel.

Section 13.03 Statements Required in Certificate or Opinion.

Each certificate or opinion with respect to compliance with a condition or covenant provided for in this Indenture and must include:

(1) a statement that the Person making such certificate or opinion has read such covenant or condition;

(2) a brief statement as to the nature and scope of the examination or investigation upon which the statements or opinions contained in such certificate or opinion are based;

(3) a statement that, in the opinion of such Person, he or she has made such examination or investigation as is necessary to enable him or her to express an informed opinion as to whether or not such covenant or condition has been complied with; and

(4) a statement as to whether or not, in the opinion of such Person, such condition or covenant has been complied with.

Section 13.04 Rules by Trustee and Agents.

The Trustee may make reasonable rules for action by or at a meeting of Holders. The Registrar or Paying Agent may make reasonable rules and set reasonable requirements for its functions.

Section 13.05 No Personal Liability of Directors, Managers, Officers, Members, Partners, Employees and Equityholders.

No past, present or future director, officer, manager, employee, incorporator, member, partner or direct or indirect stockholder, member or unitholder of the Issuer or any Restricted Subsidiaries or of any of their direct or indirect parent companies, as such, will have any liability for any obligations of the Issuer or the Guarantors under the Notes, this Indenture, the Guarantees or any Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

 

149


Section 13.06 Governing Law; Waiver of Trial by Jury; Jurisdiction.

(a) THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THIS INDENTURE, THE NOTES AND THE GUARANTEES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5- 1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

(b) Each of the Issuer, any Guarantors and the Trustee, and each Holder of a Note, by its acceptance thereof, hereby irrevocably waives, to the fullest extent permitted by applicable law, any and all right it may have to trial by jury in any legal proceeding directly or indirectly arising out of or relating to this Indenture, the securities or the transactions contemplated hereby or thereby.

(c) Each of the Issuer and each Guarantor, if any, irrevocably consents and submits, for itself and in respect of any of its assets or property, to the non-exclusive jurisdiction of any court of the State of New York or any United States federal court sitting, in each case, in the Borough of Manhattan, the City of New York, New York, United States of America, and any appellate court from any thereof in any suit, action or proceeding that may be brought in connection with this Indenture or the securities, and waives any immunity from the jurisdiction of such courts. Each of the Issuer and each Guarantor, if any, irrevocably waives, to the fullest extent permitted by law, any objection to any such suit, action or proceeding that may be brought in such courts whether on the grounds of venue, residence or domicile or on the ground that any such suit, action or proceeding has been brought in an inconvenient forum. Each of the Issuer and each Guarantor, if any, agrees, to the fullest extent that it lawfully may do so, that final judgment in any such suit, action or proceeding brought in such a court shall be conclusive and binding upon the Issuer and any Guarantor, if any, as applicable, and each of the Issuer and any Guarantor, if any, waives, to the fullest extent permitted by law, any objection to the enforcement by any competent court in the Issuer’s and the applicable Guarantor’s, as applicable, jurisdiction of organization of judgments validly obtained in any such court in New York on the basis of such suit, action or proceeding; provided, however, that neither the Issuer nor any Guarantor waive, and the foregoing provisions of this sentence shall not constitute or be deemed to constitute a waiver of, (i) any right to appeal any such judgment, to seek any stay or otherwise to seek reconsideration or review of any such judgment or (ii) any stay of execution or levy pending an appeal from, or a suit, action or proceeding for reconsideration of, any such judgment.

Section 13.07 No Adverse Interpretation of Other Agreements.

This Indenture may not be used to interpret any other indenture, loan or debt agreement of the Issuer or its Subsidiaries or of any other Person. Any such indenture, loan or debt agreement may not be used to interpret this Indenture.

 

150


Section 13.08 Successors.

All agreements of the Issuer in this Indenture and the Notes will bind its successors. All agreements of the Trustee in this Indenture will bind its successors. All agreements of each Guarantor in this Indenture will bind its successors, except as otherwise provided in Article 10 hereof.

Section 13.09 Severability.

In case any provision in this Indenture or in the Notes is invalid, illegal or unenforceable, the validity, legality and enforceability of the remaining provisions will not in any way be affected or impaired thereby.

Section 13.10 Execution; Counterpart Originals.

The parties may manually or electronically sign any number of copies of this Indenture. Each signed copy will be an original, but all of them together represent the same agreement. The exchange of copies of this Indenture and of signature pages by facsimile or electronic format (i.e., “pdf” or “tif”) transmission shall constitute effective execution and delivery of this Indenture as to the parties hereto and may be used in lieu of the original Indenture for all purposes. Signatures of the parties hereto transmitted by facsimile or electronic format (i.e., “pdf” or “tif”) shall be deemed to be their original signatures for all purposes. Delivery of an executed Indenture by one party to any other party may be made by facsimile, electronic mail (including any electronic signature complying with the New York Electronic Signatures and Records Act (N.Y. State Tech. §§ 301- 309), as amended from time to time, or other applicable law), including DocuSign, or other transmission method, and the parties hereto agree that any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

Section 13.11 Table of Contents, Headings, etc.

The Table of Contents and Headings of the Articles and Sections of this Indenture have been inserted for convenience of reference only, are not to be considered a part of this Indenture and will in no way modify or restrict any of the terms or provisions hereof.

Section 13.12 Tax Matters. Each of the parties hereto agree to cooperate and to provide the other with such information as each may have in its possession to enable the determination of whether any payments pursuant to this Indenture are subject to the withholding requirements described in Section 1471(b) of the Code or otherwise imposed pursuant to Sections 1471 through 1474 of the Code and any regulations, or agreements thereunder or official interpretations thereof (“Applicable Tax Law”). The Trustee shall be entitled to make any withholding or deduction from payments under this Indenture to the extent necessary to comply with Applicable Tax Law.

[Signatures on following page]

 

151


SIGNATURES

Dated as of October 24, 2023

 

VENTURE GLOBAL LNG, INC.
By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title: Chief Financial Officer

 

[Signature page to Indenture]


THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee and Collateral Agent

By:

 

/s/ Michele R. Shrum

Name:

 

Michele R. Shrum

Title:

 

Vice President

 

[Signature page to Indenture]


EXHIBIT A-1

[Face of Note]

 

[Insert the Global Note Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Private Placement Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Regulation S Temporary Note Legend, if applicable pursuant to the provisions of the indenture]

 

A1-1


CUSIP        1

ISIN        2

9.500% Senior Secured Notes due 2029

 

No.        [Initially]3 $      

VENTURE GLOBAL LNG, INC.

promises to pay to [Cede & Co.]4 [      ] or registered assigns, the principal sum [of                  UNITED STATES DOLLARS] or [as set forth on the Schedule of Exchanges of Interests in the Global Note attached hereto]5 on February 1, 2029.

Interest Payment Dates:    February 1 and August 1

Record Dates:        January 15 and July 15

Additional provisions of this Note are set forth on the other side of this Note.

 

1 

92332YAC5 (Rule 144A); U9220NAC5 (Reg S).

2 

US92332YAC57 (Rule 144A); USU9220NAC57 (Reg S).

3 

Include only if the Note is issued in global form.

4 

Include only if the Note is issued in global form.

5 

Include only if the Note is issued in global form.

 

A1-2


IN WITNESS HEREOF, the Issuer has caused this instrument to be duly executed.

Dated:         

 

VENTURE GLOBAL LNG, INC.
By:    
  Name:
  Title:

 

This is one of the Notes referred to in the within-mentioned Indenture:
The Bank of New York Mellon Trust Company, N.A., as Trustee
By:    
  Authorized Signatory

 

A1-3


[Back of Note]

9.500% Senior Secured Notes due 2029

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global LNG, Inc., a Delaware corporation (the “Issuer”), promises to pay or cause to be paid interest on the principal amount of this Note at 9.500% per annum from [October 24, 2023]6 until maturity. The Issuer will pay interest, if any, semi-annually in arrears on February 1 and August 1 of each year, beginning on [August 1, 2024]7, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). The Issuer will make each interest payment to the Holder of record of this Note on the immediately preceding January 15 and July 15 (whether or not a Business Day) (each, a “Record Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from [October 24, 2023].8

Interest will be computed on the basis of a 360-day year comprised of twelve 30-day months.

(2) METHOD OF PAYMENT. The Issuer will pay interest on the Notes (except defaulted interest), if any, to the Persons who are registered Holders at the close of business on the January 15 or July 15 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium, if any, and interest, if any, at the office or agency of the Paying Agent and Registrar within the City and State of New York, or, at the option of the Issuer, payment of interest, if any, may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that (a) all cash payments of principal, premium, if any, and interest with respect to Notes represented by Global Notes registered in the name of or held by DTC or its nominee will be made through the Paying Agent by wire transfer of immediately available funds to the accounts specified by the registered Holder or Holders thereof and (b) all cash payments of principal, premium, if any, and interest with respect to certificated Notes may, at the option of the Issuer, be made by wire transfer to a U.S. dollar account maintained by the payee with a bank in the United States of America if such Holder elects payment by wire transfer by giving written notice to the Trustee or the Paying Agent to such effect designating such account no later than 30 days immediately preceding the relevant due date for payment (or such other date as the Trustee may accept in its discretion). Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

 

6 

In the case of Notes issued on the Issue Date.

7 

In the case of Notes issued on the Issue Date.

8 

In the case of Notes issued on the Issue Date.

 

A1-4


(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Issuer may change the Paying Agent or Registrar without prior notice to the Holders. The Issuer or any of its Subsidiaries may act as Paying Agent or Registrar.

(4) INDENTURE. The Issuer issued the Notes under an Indenture, dated as of October 24, 2023 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among the Issuer, the Trustee and the Collateral Agent. The terms of the Notes include those stated in the Indenture. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are unsecured obligations of the Issuer. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION. At any time prior to November 1, 2028, the Issuer may on any one or more occasions redeem all or a part of the Notes, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 100% of the principal amount of the Notes redeemed, plus the Applicable Redemption Premium as of, and accrued and unpaid interest, if any, to the date of redemption.

On or after November 1, 2028, the Issuer may on any one or more occasions redeem all or any part of the Notes, upon not less than 10 nor more than 60 days’ notice, at a redemption price (expressed as a percentage of principal amount of the Notes) equal to 100.000%, plus accrued and unpaid interest, if any, on the Notes redeemed to the applicable date of redemption.

Unless the Issuer defaults in the payment of the redemption price, interest will cease to accrue on the Notes or portions thereof called for redemption on the applicable redemption date.

(6) MANDATORY REDEMPTION. The Issuer is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control Triggering Event, the Issuer will be required to make an offer (a “Change of Control Offer”) to each Holder to repurchase all or any part (equal to $2,000 or an integral multiple of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash (the “Change of Control Payment”) equal to 101% of the aggregate principal amount of Notes repurchased, plus accrued and unpaid interest, if any, on the Notes repurchased to, but not including, the date of purchase, subject to the rights of Holders of Notes on the relevant record date to receive interest due on the relevant Interest Payment Date. Within thirty days following any Change of Control Triggering Event, the Issuer will mail, or deliver electronically if the Notes are held at DTC, a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Issuer will be required to make a Collateral Asset Sale Offer or an Asset Sale Offer to the extent provided in Section 4.10 of the Indenture.

 

A1-5


(8) NOTICE OF REDEMPTION. At least 10 days but not more than 60 days before a redemption date, the Issuer will mail or cause to be mailed, by first class mail (or, in the case of Global Notes, transmit with the procedures of the Depositary), a notice of redemption to each Holder (with a copy to the Trustee) whose Notes are to be redeemed at its registered address, except that redemption notices may be mailed or transmitted more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes or a satisfaction and discharge of the Indenture pursuant to Articles 8 or 11 thereof Notes and portions of Notes selected will be in amounts of $2,000 or whole multiples of $1,000 in excess thereof; except that if all of the Notes of a Holder are to be redeemed or purchased, the entire outstanding amount of Notes held by such Holder shall be redeemed or purchased.

Any such redemption may, at the Issuer’s discretion, be subject to one or more conditions precedent, including completion of any related Equity Offerings, Change of Control or other transaction. In addition, if such redemption is subject to the satisfaction of one or more conditions precedent, the related notice shall describe each such condition, and if applicable, shall state that, in the Issuer’s discretion, the date of redemption may be delayed until such time as any or all such conditions shall be satisfied or waived, or such redemption or purchase may not occur and such notice may be rescinded in the event that any or all such conditions shall not have been satisfied or waived by the date of redemption, or by the date of redemption as so delayed. In addition, the Issuer may provide in such notice that payment of the redemption price and performance of the Issuer’s obligations with respect to such redemption may be performed by another Person (it being understood that any such provision for payment by another Person will not relieve the Issuer and the Guarantors, if any, from their obligations with respect to such redemption).

(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Issuer may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Issuer need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Issuer need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the next succeeding Interest Payment Date.

(10) PERSONS DEEMED OWNERS. The registered Holder may be treated as the owner of it for all purposes. Only registered Holders have rights under the Indenture.

(11) AMENDMENT, SUPPLEMENT AND WAIVER. Subject to certain exceptions, the Indenture, the Notes or the Guarantees may be amended or supplemented as provided in the Indenture.

(12) DEFAULTS AND REMEDIES. The Events of Default relating to the Notes are defined in Section 6.01 of the Indenture. If any Event of Default (other than an Event of Default of the type specified in clause (h) or (i) of Section 6.01 of the Indenture with respect to the Issuer) occurs and is continuing under the Indenture, the Trustee or the Holders of not less than 30% in aggregate principal amount of all of the then outstanding Notes may, by written notice to the Issuer

 

A1-6


and the Trustee, may declare all of the Notes to be due and payable immediately. Upon any such declaration, the Notes shall become due and payable immediately. Notwithstanding the foregoing, in the case of an Event of Default arising under clause (h) or (i) of Section 6.01 of the Indenture with respect to the Issuer, all outstanding Notes will become due and payable immediately without further action or notice. Holders may not enforce the Indenture, the Notes, the Security Documents or the Guarantees except as provided in the Indenture. Subject to certain limitations, Holders of a majority in aggregate principal amount of all the Notes then outstanding may direct the Trustee in its exercise of any trust or power.

(13) TRUSTEE DEALINGS WITH ISSUER. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Issuer or its Affiliates, and may otherwise deal with the Issuer or its Affiliates, as if it were not the Trustee.

(14) GUARANTEES. The Issuer’s obligations under the Notes are fully and unconditionally guaranteed, jointly and severally, by the Guarantors, if any, to the extent set forth in Article 10 of the Indenture.

(15) SECURITY. The Notes and the related Guarantees, if any, will be secured by the Collateral on the terms and subject to the conditions set forth in the Indenture and the Security Documents. The Collateral Agent holds the Collateral in trust for the benefit of the Holders of the Notes, in each case pursuant to the Security Documents, the Collateral Agency Agreement and any Acceptable Intercreditor Agreement. Each Holder, by accepting this Note, consents and agrees to the terms of the Security Documents (including the provisions providing for the foreclosure and release of Collateral), the Collateral Agency Agreement and any Acceptable Intercreditor Agreement, each as may be in effect or may be amended from time to time in accordance with their terms and the Indenture, and authorizes and directs the Trustee, the Collateral Agent and any common collateral agent (if any) to enter into the Security Documents, the Collateral Agency Agreement and any Acceptable Intercreditor Agreement at any time after the Issue Date, if applicable, and to perform its obligations and exercise its rights thereunder in accordance therewith.

(16) NO RECOURSE AGAINST OTHERS. No director, officer, employee, incorporator or stockholder of the Issuer or any Guarantor, as such, will have any liability for any obligations of the Issuer or the Guarantors under the Notes, the Indenture, the Guarantees, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(17) AUTHENTICATION. This Note will not be entitled to any benefit under the Indenture or be valid or obligatory for any purposes until authenticated by the manual signature of the Trustee or an authenticating agent.

(18) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

 

A1-7


(19) CUSIP NUMBERS AND ISINS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Issuer has caused CUSIP numbers and ISINs to be printed on the Notes, and the Trustee may use CUSIP numbers and ISINs in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

(20) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THE NOTES AND THE GUARANTEES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

The Issuer will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

 

A1-8


ASSIGNMENT FORM

To assign this Note, fill in the form below:

 

(I) or (we) assign and transfer this Note to:                                             
   (Insert assignee’s legal name)

 

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

 

 

 

 

(Print or type assignee’s name, address and zip code)

and irrevocably appoint                              to transfer this Note on the books of the Issuer. The agent may substitute another to act for him.

Date:        

 

Your Signature:              

(Sign exactly as your name appears on the face of this Note)

Signature Guarantee*:        

* Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A1-9


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Issuer pursuant to Section 4.10 or 4.15 of the Indenture, check the appropriate box below:

☐ Section 4.10      ☐ Section 4.15

If you want to elect to have only part of the Note purchased by the Issuer pursuant to Section 4.10 or Section 4.15 of the Indenture, state the amount you elect to have purchased:

$         

Date:        

 

Your Signature:              

(Sign exactly as your name appears on the face of this Note)

Tax Identification No.:  

 

Signature Guarantee*:        

* Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A1-10


SCHEDULE OF EXCHANGES OF INTERESTS IN THE GLOBAL NOTE *

The initial outstanding principal amount of this Global Note is $    . The following exchanges of a part of this Global Note for an interest in another Global Note or for a Definitive Note, or exchanges of a part of another Global Note or Definitive Note for an interest in this Global Note, have been made:

 

Date of Exchange

  

Amount of

decrease in

Principal

Amount

of

this Global Note

  

Amount of

increase in

Principal Amount

of

this Global Note

  

Principal

Amount

of this Global

Note

following such

decrease

(or increase)

  

Signature of

authorized

officer

of Trustee or

Custodian

 

*

This schedule should be included only if the Note is issued in global form.

 

A1-11


EXHIBIT A-2

[Face of Note]

 

[Insert the Global Note Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Private Placement Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Regulation S Temporary Note Legend, if applicable pursuant to the provisions of the indenture]

 

A2-1


CUSIP         9

ISIN        10

9.875% Senior Secured Notes due 2032

 

No.           [Initially]11 $       

VENTURE GLOBAL LNG, INC.

promises to pay to [Cede & Co.]12 [       ] or registered assigns, the principal sum [of                   UNITED STATES DOLLARS] or [as set forth on the Schedule of Exchanges of Interests in the Global Note attached hereto]13 on February 1, 2032.

Interest Payment Dates:    February 1 and August 1

Record Dates:        January 15 and July 15

Additional provisions of this Note are set forth on the other side of this Note.

 

9 

92332YAD3 (Rule 144A); U9220NAD3 (Reg S).

10 

US92332YAD31 (Rule 144A); USU9220NAD31 (Reg S).

11 

Include only if the Note is issued in global form.

12 

Include only if the Note is issued in global form.

13 

Include only if the Note is issued in global form.

 

A2-2


IN WITNESS HEREOF, the Issuer has caused this instrument to be duly executed.

Dated:         

 

VENTURE GLOBAL LNG, INC.

By:

   
 

Name:

 

Title:

 

This is one of the Notes referred to in the within-mentioned Indenture:
The Bank of New York Mellon Trust Company, N.A., as Trustee
By:    
  Authorized Signatory

 

 

A2-3


[Back of Note]

9.875% Senior Secured Notes due 2032

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global LNG, Inc., a Delaware corporation (the “Issuer”), promises to pay or cause to be paid interest on the principal amount of this Note at 9.875% per annum from [October 24, 2023]14 until maturity. The Issuer will pay interest, if any, semi-annually in arrears on February 1 and August 1 of each year, beginning on [August 1, 2024]15, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). The Issuer will make each interest payment to the Holder of record of this Note on the immediately preceding January 15 and July 15 (whether or not a Business Day) (each, a “Record Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from [October 24, 2023].16 Interest will be computed on the basis of a 360-day year comprised of twelve 30-day months.

(2) METHOD OF PAYMENT. The Issuer will pay interest on the Notes (except defaulted interest), if any, to the Persons who are registered Holders at the close of business on the January 15 or July 15 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium, if any, and interest, if any, at the office or agency of the Paying Agent and Registrar within the City and State of New York, or, at the option of the Issuer, payment of interest, if any, may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that (a) all cash payments of principal, premium, if any, and interest with respect to Notes represented by Global Notes registered in the name of or held by DTC or its nominee will be made through the Paying Agent by wire transfer of immediately available funds to the accounts specified by the registered Holder or Holders thereof and (b) all cash payments of principal, premium, if any, and interest with respect to certificated Notes may, at the option of the Issuer, be made by wire transfer to a U.S. dollar account maintained by the payee with a bank in the United States of America if such Holder elects payment by wire transfer by giving written notice to the Trustee or the Paying Agent to such effect designating such account no later than 30 days immediately preceding the relevant due date for payment (or such other date as the Trustee may accept in its discretion). Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Issuer may change the Paying Agent or Registrar without prior notice to the Holders. The Issuer or any of its Subsidiaries may act as Paying Agent or Registrar.

 

14 

In the case of Notes issued on the Issue Date.

15 

In the case of Notes issued on the Issue Date.

16 

In the case of Notes issued on the Issue Date.

 

A2-4


(4) INDENTURE. The Issuer issued the Notes under an Indenture, dated as of October 24, 2023 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among the Issuer, the Trustee and the Collateral Agent. The terms of the Notes include those stated in the Indenture. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are unsecured obligations of the Issuer. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

(a) At any time prior to February 1, 2027, the Issuer may on any one or more occasions redeem up to 40% of the aggregate principal amount of Notes issued under the Indenture, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 109.875% of the principal amount of the Notes redeemed, plus accrued and unpaid interest, if any, to the date of redemption with an amount not to exceed the amount of net cash proceeds from one or more Equity Offerings consummated after the Issue Date; provided that:

(i) at least 50% of the aggregate principal amount of Notes issued under the Indenture on the Issue Date (excluding Notes held by the Issuer and its Subsidiaries) remains outstanding immediately after the occurrence of such redemption (unless all such Notes are otherwise repurchased or redeemed pursuant to another provision described under Article 3 of the Indenture); and

(ii) the redemption occurs within 180 days of the date of the closing of such Equity Offerings.

(b) At any time prior to February 1, 2027, the Issuer may on any one or more occasions redeem all or a part of the Notes, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 100% of the principal amount of the Notes redeemed, plus the Applicable Redemption Premium as of, and accrued and unpaid interest, if any, to the date of redemption.

(c) On or after February 1, 2027, the Issuer may on any one or more occasions redeem all or a part of the Notes, upon not less than 10 nor more than 60 days’ notice, at the redemption prices (expressed as percentages of principal amount) set forth below, plus accrued and unpaid interest, if any, on the Notes redeemed, to the applicable date of redemption, if redeemed during the twelve-month period beginning on February 1 of the years indicated below:

 

Year

   Percentage  

2027

     104.938%  

2028

     102.469%  

2029 and thereafter

     100.000%  

 

A2-5


Unless the Issuer defaults in the payment of the redemption price, interest will cease to accrue on the Notes or portions thereof called for redemption on the applicable redemption date.

(6) MANDATORY REDEMPTION. The Issuer is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control Triggering Event, the Issuer will be required to make an offer (a “Change of Control Offer”) to each Holder to repurchase all or any part (equal to $2,000 or an integral multiple of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash (the “Change of Control Payment”) equal to 101% of the aggregate principal amount of Notes repurchased, plus accrued and unpaid interest, if any, on the Notes repurchased to, but not including, the date of purchase, subject to the rights of Holders of Notes on the relevant record date to receive interest due on the relevant Interest Payment Date. Within thirty days following any Change of Control Triggering Event, the Issuer will mail, or deliver electronically if the Notes are held at DTC, a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Issuer will be required to make a Collateral Asset Sale Offer or an Asset Sale Offer to the extent provided in Section 4.10 of the Indenture.

(8) NOTICE OF REDEMPTION. At least 10 days but not more than 60 days before a redemption date, the Issuer will mail or cause to be mailed, by first class mail (or, in the case of Global Notes, transmit with the procedures of the Depositary), a notice of redemption to each Holder (with a copy to the Trustee) whose Notes are to be redeemed at its registered address, except that redemption notices may be mailed or transmitted more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes or a satisfaction and discharge of the Indenture pursuant to Articles 8 or 11 thereof Notes and portions of Notes selected will be in amounts of $2,000 or whole multiples of $1,000 in excess thereof; except that if all of the Notes of a Holder are to be redeemed or purchased, the entire outstanding amount of Notes held by such Holder shall be redeemed or purchased.

Any such redemption may, at the Issuer’s discretion, be subject to one or more conditions precedent, including completion of any related Equity Offerings, Change of Control or other transaction. In addition, if such redemption is subject to the satisfaction of one or more conditions precedent, the related notice shall describe each such condition, and if applicable, shall state that, in the Issuer’s discretion, the date of redemption may be delayed until such time as any or all such conditions shall be satisfied or waived, or such redemption or purchase may not occur and such notice may be rescinded in the event that any or all such conditions shall not have been satisfied or waived by the date of redemption, or by the date of redemption as so delayed. In addition, the Issuer may provide in such notice that payment of the redemption price and performance of the Issuer’s obligations with respect to such redemption may be performed by another Person (it being understood that any such provision for payment by another Person will not relieve the Issuer and the Guarantors, if any, from their obligations with respect to such redemption).

 

A2-6


(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Issuer may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Issuer need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Issuer need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the next succeeding Interest Payment Date.

(10) PERSONS DEEMED OWNERS. The registered Holder may be treated as the owner of it for all purposes. Only registered Holders have rights under the Indenture.

(11) AMENDMENT, SUPPLEMENT AND WAIVER. Subject to certain exceptions, the Indenture, the Notes or the Guarantees may be amended or supplemented as provided in the Indenture.

(12) DEFAULTS AND REMEDIES. The Events of Default relating to the Notes are defined in Section 6.01 of the Indenture. If any Event of Default (other than an Event of Default of the type specified in clause (h) or (i) of Section 6.01 of the Indenture with respect to the Issuer) occurs and is continuing under the Indenture, the Trustee or the Holders of not less than 30% in aggregate principal amount of all of the then outstanding Notes may, by written notice to the Issuer and the Trustee, may declare all of the Notes to be due and payable immediately. Upon any such declaration, the Notes shall become due and payable immediately. Notwithstanding the foregoing, in the case of an Event of Default arising under clause (h) or (i) of Section 6.01 of the Indenture with respect to the Issuer, all outstanding Notes will become due and payable immediately without further action or notice. Holders may not enforce the Indenture, the Notes, the Security Documents or the Guarantees except as provided in the Indenture. Subject to certain limitations, Holders of a majority in aggregate principal amount of all the Notes then outstanding may direct the Trustee in its exercise of any trust or power.

(13) TRUSTEE DEALINGS WITH ISSUER. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Issuer or its Affiliates, and may otherwise deal with the Issuer or its Affiliates, as if it were not the Trustee.

(14) GUARANTEES. The Issuer’s obligations under the Notes are fully and unconditionally guaranteed, jointly and severally, by the Guarantors, if any, to the extent set forth in Article 10 of the Indenture.

(15) SECURITY. The Notes and the related Guarantees, if any, will be secured by the Collateral on the terms and subject to the conditions set forth in the Indenture and the Security Documents. The Collateral Agent holds the Collateral in trust for the benefit of the Holders of the Notes, in each case pursuant to the Security Documents, the Collateral Agency Agreement and any Acceptable Intercreditor Agreement. Each Holder, by accepting this Note, consents and agrees to the terms of the Security Documents (including the provisions providing for the foreclosure and release of Collateral), the Collateral Agency Agreement and any Acceptable

 

A2-7


Intercreditor Agreement, each as may be in effect or may be amended from time to time in accordance with their terms and the Indenture, and authorizes and directs the Trustee, the Collateral Agent and any common collateral agent (if any) to enter into the Security Documents, the Collateral Agency Agreement and any Acceptable Intercreditor Agreement at any time after the Issue Date, if applicable, and to perform its obligations and exercise its rights thereunder in accordance therewith.

(16) NO RECOURSE AGAINST OTHERS. No director, officer, employee, incorporator or stockholder of the Issuer or any Guarantor, as such, will have any liability for any obligations of the Issuer or the Guarantors under the Notes, the Indenture, the Guarantees, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(17) AUTHENTICATION. This Note will not be entitled to any benefit under the Indenture or be valid or obligatory for any purposes until authenticated by the manual signature of the Trustee or an authenticating agent.

(18) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(19) CUSIP NUMBERS AND ISINS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Issuer has caused CUSIP numbers and ISINs to be printed on the Notes, and the Trustee may use CUSIP numbers and ISINs in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

(20) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THE NOTES AND THE GUARANTEES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

The Issuer will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

 

A2-8


ASSIGNMENT FORM

To assign this Note, fill in the form below:

 

(I) or (we) assign and transfer this Note to:                                             
   (Insert assignee’s legal name)

 

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

 

 

 

 

(Print or type assignee’s name, address and zip code)

and irrevocably appoint                              to transfer this Note on the books of the Issuer. The agent may substitute another to act for him.

Date:        

 

Your Signature:              

(Sign exactly as your name appears on the face of this Note)

Signature Guarantee*:        

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A2-9


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Issuer pursuant to Section 4.10 or 4.15 of the Indenture, check the appropriate box below:

☐ Section 4.10      ☐ Section 4.15

If you want to elect to have only part of the Note purchased by the Issuer pursuant to Section 4.10 or Section 4.15 of the Indenture, state the amount you elect to have purchased:

$         

Date:        

 

 

Your Signature:                 

(Sign exactly as your name appears on the face of this Note)

Tax Identification No.:             

Signature Guarantee*:        

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A2-10


SCHEDULE OF EXCHANGES OF INTERESTS IN THE GLOBAL NOTE *

The initial outstanding principal amount of this Global Note is $    . The following exchanges of a part of this Global Note for an interest in another Global Note or for a Definitive Note, or exchanges of a part of another Global Note or Definitive Note for an interest in this Global Note, have been made:

 

Date of Exchange

  

Amount of

decrease in

Principal

Amount

of

   this Global Note   

  

Amount of

increase in

Principal

Amount

of

   this Global Note   

  

Principal

Amount

of this Global

Note

following such

decrease

   (or increase)   

  

Signature of

authorized

officer

of Trustee or

   Custodian   

 

*

This schedule should be included only if the Note is issued in global form.

 

A2-11


EXHIBIT B

FORM OF CERTIFICATE OF TRANSFER (2029 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

Re: 9.500% Senior Secured Notes due 2029

Reference is hereby made to the Indenture, dated as of October 24, 2023 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

           , (the “Transferor”) owns and proposes to transfer the Note[s] or interest in such Note[s] specified in Annex A hereto, in the principal amount of $        in such Note[s] or interests (the “Transfer”), to            (the “Transferee”), as further specified in Annex A hereto. In connection with the Transfer, the Transferor hereby certifies that:

[CHECK ALL THAT APPLY]

1. ☐ Check if Transferee will take delivery of a beneficial interest in the 144A Global Note or a Restricted Definitive Note pursuant to Rule 144A. The Transfer is being effected pursuant to and in accordance with Rule 144A under the Securities Act of 1933, as amended (the “Securities Act”), and, accordingly, the Transferor hereby further certifies that the beneficial interest or Definitive Note is being transferred to a Person that the Transferor reasonably believes is purchasing the beneficial interest or Definitive Note for its own account, or for one or more accounts with respect to which such Person exercises sole investment discretion, and such Person and each such account is a “qualified institutional buyer” within the meaning of Rule 144A in a transaction meeting the requirements of Rule 144A, and such Transfer is in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the 144A Global Note and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

 

B-1


2. Check if Transferee will take delivery of a beneficial interest in the Regulation S Temporary Global Note, the Regulation S Permanent Global Note or a Restricted Definitive Note pursuant to Regulation S. The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and, accordingly, the Transferor hereby further certifies that (i) the Transfer is not being made to a Person in the United States and (x) at the time the buy order was originated, the Transferee was outside the United States or such Transferor and any Person acting on its behalf reasonably believed and believes that the Transferee was outside the United States or (y) the transaction was executed in, on or through the facilities of a designated offshore securities market and neither such Transferor nor any Person acting on its behalf knows that the transaction was prearranged with a buyer in the United States, (ii) no directed selling efforts have been made in contravention of the requirements of Rule 903(b) or Rule 904(b) of Regulation S under the Securities Act, (iii) the transaction is not part of a plan or scheme to evade the registration requirements of the Securities Act and (iv) if the proposed transfer is being made prior to the expiration of the Restricted Period, the transfer is not being made to a U.S. Person or for the account or benefit of a U.S. Person (other than an Initial Purchaser). Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on Transfer enumerated in the Private Placement Legend printed on the Regulation S Permanent Global Note, the Regulation S Temporary Global Note, and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

3. ☐ Check and complete if Transferee will take delivery of a beneficial interest in the IAI Global Note or a Restricted Definitive Note pursuant to any provision of the Securities Act other than Rule 144A or Regulation S. The Transfer is being effected in compliance with the transfer restrictions applicable to beneficial interests in Restricted Global Notes and Restricted Definitive Notes and pursuant to and in accordance with the Securities Act and any applicable blue sky securities laws of any state of the United States, and accordingly the Transferor hereby further certifies that (check one):

(a) ☐ such Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act;

or

(b) ☐ such Transfer is being effected to the Issuer or a subsidiary thereof; or

(c) ☐ such Transfer is being effected pursuant to an effective registration statement under the Securities Act and in compliance with the prospectus delivery requirements of the Securities Act;

or

(d) ☐ such Transfer is being effected to an Institutional Accredited Investor and pursuant to an exemption from the registration requirements of the Securities Act other than Rule 144A, Rule 144, Rule 903 or Rule 904, and the Transferor hereby further certifies that it has not engaged in any general solicitation within the meaning of Regulation D under the Securities Act

 

B-2


and the Transfer complies with the transfer restrictions applicable to beneficial interests in a Restricted Global Note or Restricted Definitive Notes and the requirements of the exemption claimed, which certification is supported by (1) a certificate executed by the Transferee in the form of Exhibit D to the Indenture and (2) if such Transfer is in respect of a principal amount of Notes at the time of transfer of less than $250,000, an Opinion of Counsel provided by the Transferor or the Transferee (a copy of which the Transferor has attached to this certification), to the effect that such Transfer is in compliance with the Securities Act. Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the IAI Global Note and/or the Restricted Definitive Notes and in the Indenture and the Securities Act.

4. Check if Transferee will take delivery of a beneficial interest in an Unrestricted Global Note or of an Unrestricted Definitive Note.

(a) ☐ Check if Transfer is pursuant to Rule 144. (i) The Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

(b) ☐ Check if Transfer is Pursuant to Regulation S. (i) The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

(c) ☐ Check if Transfer is Pursuant to Other Exemption. (i) The Transfer is being effected pursuant to and in compliance with an exemption from the registration requirements of the Securities Act other than Rule 144, Rule 903 or Rule 904 and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any State of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will not be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes or Restricted Definitive Notes and in the Indenture.

 

B-3


This certificate and the statements contained herein are made for your benefit and the benefit of the Issuer.

 

 
[Insert Name of Transferor]
By:    
  Name:
  Title:

Dated:            

 

B-4


ANNEX A TO CERTIFICATE OF TRANSFER

1. The Transferor owns and proposes to transfer the following:

[CHECK ONE OF (a) OR (b)]

(a) ☐ a beneficial interest in the:

(i) ☐ 144A Global Note (CUSIP     ), or

(ii) ☐ Regulation S Global Note (CUSIP     ), or

(iii) ☐ IAI Global Note (CUSIP     ); or

(b) ☐ a Restricted Definitive Note.

2. After the Transfer the Transferee will hold:

[CHECK ONE]

(a) ☐ a beneficial interest in the:

(i) ☐ 144A Global Note (CUSIP     ), or

(ii) ☐ Regulation S Global Note (CUSIP     ), or

(iii) ☐ IAI Global Note (CUSIP     ); or

(iv) ☐ Unrestricted Global Note (CUSIP     ); or

(b) ☐ a Restricted Definitive Note; or

(c) ☐ an Unrestricted Definitive Note,

in accordance with the terms of the Indenture.

 

B-5


FORM OF CERTIFICATE OF TRANSFER (2032 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

Re: 9.875% Senior Secured Notes due 2032

Reference is hereby made to the Indenture, dated as of October 24, 2023 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

              , (the “Transferor”) owns and proposes to transfer the Note[s] or interest in such Note[s] specified in Annex A hereto, in the principal amount of $       in such Note[s] or interests (the “Transfer”), to (the “Transferee”), as further specified in Annex A hereto. In connection with the Transfer, the Transferor hereby certifies that:

[CHECK ALL THAT APPLY]

1. ☐ Check if Transferee will take delivery of a beneficial interest in the 144A Global Note or a Restricted Definitive Note pursuant to Rule 144A. The Transfer is being effected pursuant to and in accordance with Rule 144A under the Securities Act of 1933, as amended (the “Securities Act”), and, accordingly, the Transferor hereby further certifies that the beneficial interest or Definitive Note is being transferred to a Person that the Transferor reasonably believes is purchasing the beneficial interest or Definitive Note for its own account, or for one or more accounts with respect to which such Person exercises sole investment discretion, and such Person and each such account is a “qualified institutional buyer” within the meaning of Rule 144A in a transaction meeting the requirements of Rule 144A, and such Transfer is in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the 144A Global Note and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

2. ☐ Check if Transferee will take delivery of a beneficial interest in the Regulation S Temporary Global Note, the Regulation S Permanent Global Note or a Restricted Definitive Note pursuant to Regulation S. The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and, accordingly, the

 

B-6


Transferor hereby further certifies that (i) the Transfer is not being made to a Person in the United States and (x) at the time the buy order was originated, the Transferee was outside the United States or such Transferor and any Person acting on its behalf reasonably believed and believes that the Transferee was outside the United States or (y) the transaction was executed in, on or through the facilities of a designated offshore securities market and neither such Transferor nor any Person acting on its behalf knows that the transaction was prearranged with a buyer in the United States, (ii) no directed selling efforts have been made in contravention of the requirements of Rule 903(b) or Rule 904(b) of Regulation S under the Securities Act, (iii) the transaction is not part of a plan or scheme to evade the registration requirements of the Securities Act and (iv) if the proposed transfer is being made prior to the expiration of the Restricted Period, the transfer is not being made to a U.S. Person or for the account or benefit of a U.S. Person (other than an Initial Purchaser). Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on Transfer enumerated in the Private Placement Legend printed on the Regulation S Permanent Global Note, the Regulation S Temporary Global Note, and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

3. ☐ Check and complete if Transferee will take delivery of a beneficial interest in the IAI Global Note or a Restricted Definitive Note pursuant to any provision of the Securities Act other than Rule 144A or Regulation S. The Transfer is being effected in compliance with the transfer restrictions applicable to beneficial interests in Restricted Global Notes and Restricted Definitive Notes and pursuant to and in accordance with the Securities Act and any applicable blue sky securities laws of any state of the United States, and accordingly the Transferor hereby further certifies that (check one):

(a) ☐ such Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act;

or

(b) ☐ such Transfer is being effected to the Issuer or a subsidiary thereof; or

(c) ☐ such Transfer is being effected pursuant to an effective registration statement under the Securities Act and in compliance with the prospectus delivery requirements of the Securities Act;

or

(d) ☐ such Transfer is being effected to an Institutional Accredited Investor and pursuant to an exemption from the registration requirements of the Securities Act other than Rule 144A, Rule 144, Rule 903 or Rule 904, and the Transferor hereby further certifies that it has not engaged in any general solicitation within the meaning of Regulation D under the Securities Act and the Transfer complies with the transfer restrictions applicable to beneficial interests in a Restricted Global Note or Restricted Definitive Notes and the requirements of the exemption claimed, which certification is supported by (1) a certificate executed by the Transferee in the form of Exhibit D to the Indenture and (2) if such Transfer is in respect of a principal amount of Notes at the time of transfer of less than $250,000, an Opinion of Counsel provided by the Transferor or

 

B-7


the Transferee (a copy of which the Transferor has attached to this certification), to the effect that such Transfer is in compliance with the Securities Act. Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the IAI Global Note and/or the Restricted Definitive Notes and in the Indenture and the Securities Act.

4. Check if Transferee will take delivery of a beneficial interest in an Unrestricted Global Note or of an Unrestricted Definitive Note.

(a) ☐ Check if Transfer is pursuant to Rule 144. (i) The Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

(b) ☐ Check if Transfer is Pursuant to Regulation S. (i) The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

(c) ☐ Check if Transfer is Pursuant to Other Exemption. (i) The Transfer is being effected pursuant to and in compliance with an exemption from the registration requirements of the Securities Act other than Rule 144, Rule 903 or Rule 904 and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any State of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will not be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes or Restricted Definitive Notes and in the Indenture.

 

B-8


This certificate and the statements contained herein are made for your benefit and the benefit of the Issuer.

 

 
[Insert Name of Transferor]
By:    
  Name:
  Title:

Dated:            

 

B-9


ANNEX A TO CERTIFICATE OF TRANSFER

1. The Transferor owns and proposes to transfer the following:

[CHECK ONE OF (a) OR (b)]

(a) ☐ a beneficial interest in the:

(i) ☐ 144A Global Note (CUSIP     ), or

(ii) ☐ Regulation S Global Note (CUSIP     ), or

(iii) ☐ IAI Global Note (CUSIP     ); or

(b) ☐ a Restricted Definitive Note.

2. After the Transfer the Transferee will hold:

[CHECK ONE]

(a) ☐ a beneficial interest in the:

(i) ☐ 144A Global Note (CUSIP     ), or

(ii) ☐ Regulation S Global Note (CUSIP     ), or

(iii) ☐ IAI Global Note (CUSIP     ); or

(iv) ☐ Unrestricted Global Note (CUSIP     ); or

(b) ☐ a Restricted Definitive Note; or

(c) ☐ an Unrestricted Definitive Note,

in accordance with the terms of the Indenture.

 

B-10


EXHIBIT C

FORM OF CERTIFICATE OF EXCHANGE (2029 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

Re: 9.500% Senior Secured Notes due 2029

(CUSIP [    ]17)

Reference is hereby made to the Indenture, dated as of October 24, 2023 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

              , (the “Owner”) owns and proposes to exchange the Note[s] or interest in such Note[s] specified herein, in the principal amount of $       in such Note[s] or interests (the “Exchange”). In connection with the Exchange, the Owner hereby certifies that:

1. Exchange of Restricted Definitive Notes or Beneficial Interests in a Restricted Global Note for Unrestricted Definitive Notes or Beneficial Interests in an Unrestricted Global Note

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to beneficial interest in an Unrestricted Global Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a beneficial interest in an Unrestricted Global Note in an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Global Notes and pursuant to and in accordance with the Securities Act of 1933, as amended (the “Securities Act”), (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest in an Unrestricted Global Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

 

17 

92332YAC5 (Rule 144A); U9220NAC5 (Reg S).

 

C-1


(b) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Unrestricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(c) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in an Unrestricted Global Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for a beneficial interest in an Unrestricted Global Note, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(d) ☐ Check if Exchange is from Restricted Definitive Note to Unrestricted Definitive Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Unrestricted Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Unrestricted Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

2. Exchange of Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes for Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Restricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a Restricted Definitive Note with an equal principal amount, the Owner hereby certifies that the Restricted Definitive Note is being acquired for the Owner’s own account without transfer. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the Restricted Definitive Note issued will continue to be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Definitive Note and in the Indenture and the Securities Act.

 

C-2


(b) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in a Restricted Global Note. In connection with the Exchange of the Owner’s Restricted Definitive Note for a beneficial interest in the [CHECK ONE] ☐ 144A Global Note, ☐ Regulation S Global Note, ☐ IAI Global Note with an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer and (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, and in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the beneficial interest issued will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the relevant Restricted Global Note and in the Indenture and the Securities Act.

This certificate and the statements contained herein are made for your benefit and the benefit of the Issuer.

 

 

[Insert Name of Transferor]

By:

   
 

Name:

 

Title:

Dated:         

 

C-3


FORM OF CERTIFICATE OF EXCHANGE (2032 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

Re: 9.875% Senior Secured Notes due 2032

(CUSIP [   ]18)

Reference is hereby made to the Indenture, dated as of October 24, 2023 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

               , (the “Owner”) owns and proposes to exchange the Note[s] or interest in such Note[s] specified herein, in the principal amount of $       in such Note[s] or interests (the “Exchange”). In connection with the Exchange, the Owner hereby certifies that:

1. Exchange of Restricted Definitive Notes or Beneficial Interests in a Restricted Global Note for Unrestricted Definitive Notes or Beneficial Interests in an Unrestricted Global Note

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to beneficial interest in an Unrestricted Global Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a beneficial interest in an Unrestricted Global Note in an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Global Notes and pursuant to and in accordance with the Securities Act of 1933, as amended (the “Securities Act”), (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest in an Unrestricted Global Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

 

18 

92332YAD3 (Rule 144A); U9220NAD3 (Reg S).

 

C-4


(b) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Unrestricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(c) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in an Unrestricted Global Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for a beneficial interest in an Unrestricted Global Note, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(d) ☐ Check if Exchange is from Restricted Definitive Note to Unrestricted Definitive Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Unrestricted Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Unrestricted Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

2. Exchange of Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes for Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Restricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a Restricted Definitive Note with an equal principal amount, the Owner hereby certifies that the Restricted Definitive Note is being acquired for the Owner’s own account without transfer. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the Restricted Definitive Note issued will continue to be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Definitive Note and in the Indenture and the Securities Act.

(b) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in a Restricted Global Note. In connection with the Exchange of the Owner’s Restricted Definitive Note for a beneficial interest in the [CHECK ONE] ☐ 144A Global Note, ☐ Regulation S Global Note, ☐ IAI Global Note with an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer and (ii) such

 

C-5


Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, and in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the beneficial interest issued will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the relevant Restricted Global Note and in the Indenture and the Securities Act.

This certificate and the statements contained herein are made for your benefit and the benefit of the Issuer.

 

 

[Insert Name of Transferor]

By:

   

Name:

 

Title:

 

 

Dated:    

 

C-6


EXHIBIT D

FORM OF CERTIFICATE FROM

ACQUIRING INSTITUTIONAL ACCREDITED INVESTOR (2029 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

Re: 9.500% Senior Secured Notes due 2029

Reference is hereby made to the Indenture, dated as of October 24, 2023 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

In connection with our proposed purchase of $      aggregate principal amount of:

(a) ☐ a beneficial interest in a Global Note, or

(b) ☐ a Definitive Note,

we confirm that:

1. We understand that any subsequent transfer of the Notes or any interest therein is subject to certain restrictions and conditions set forth in the Indenture and the undersigned agrees to be bound by, and not to resell, pledge or otherwise transfer the Notes or any interest therein except in compliance with, such restrictions and conditions and the Securities Act of 1933, as amended (the “Securities Act”).

2. We understand that the offer and sale of the Notes have not been registered under the Securities Act, and that the Notes and any interest therein may not be offered or sold except as permitted in the following sentence. We agree, on our own behalf and on behalf of any accounts for which we are acting as hereinafter stated, that if we should sell the Notes or any interest therein, we will do so only (A) to the Issuer or any subsidiary thereof, (B) in accordance with Rule 144A under the Securities Act to a “qualified institutional buyer” (as defined therein), (C) to an institutional “accredited investor” (as defined below) that, prior to such transfer, furnishes (or has furnished on its behalf by a U.S. broker-dealer) to you and to the Issuer a signed letter substantially in the form of this letter and, if such transfer is in respect of a principal amount of Notes, at the time of transfer of less than $250,000, an Opinion of Counsel in form reasonably acceptable to the

 

D-1


Issuer to the effect that such transfer is in compliance with the Securities Act, (D) outside the United States in accordance with Rule 904 of Regulation S under the Securities Act, (E) pursuant to the provisions of Rule 144 under the Securities Act or (F) pursuant to an effective registration statement under the Securities Act, and we further agree to provide to any Person purchasing the Definitive Note or beneficial interest in a Global Note from us in a transaction meeting the requirements of clauses (A) through (E) of this paragraph a notice advising such purchaser that resales thereof are restricted as stated herein.

3. We understand that, on any proposed resale of the Notes or beneficial interest therein, we will be required to furnish to you and the Issuer such certifications, legal opinions and other information as you and the Issuer may reasonably require to confirm that the proposed sale complies with the foregoing restrictions. We further understand that the Notes purchased by us will bear a legend to the foregoing effect.

4. We are an institutional “accredited investor” (as defined in Rule 501(a)(1), (2), (3) or (7) of Regulation D under the Securities Act) and have such knowledge and experience in financial and business matters as to be capable of evaluating the merits and risks of our investment in the Notes, and we and any accounts for which we are acting are each able to bear the economic risk of our or its investment.

5. We are acquiring the Notes or beneficial interest therein purchased by us for our own account or for one or more accounts (each of which is an institutional “accredited investor”) as to each of which we exercise sole investment discretion.

You and the Issuer are entitled to rely upon this letter and are irrevocably authorized to produce this letter or a copy hereof to any interested party in any administrative or legal proceedings or official inquiry with respect to the matters covered hereby.

 

 

[Insert Name of Accredited Investor]

By:

   
 

Name:

 

Title:

 

Dated:    

 

D-2


FORM OF CERTIFICATE FROM

ACQUIRING INSTITUTIONAL ACCREDITED INVESTOR (2032 NOTES)

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

Re: 9.875% Senior Secured Notes due 2032

Reference is hereby made to the Indenture, dated as of October 24, 2023 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

In connection with our proposed purchase of $      aggregate principal amount of:

(a) ☐ a beneficial interest in a Global Note, or

(b) ☐ a Definitive Note, we confirm that:

1. We understand that any subsequent transfer of the Notes or any interest therein is subject to certain restrictions and conditions set forth in the Indenture and the undersigned agrees to be bound by, and not to resell, pledge or otherwise transfer the Notes or any interest therein except in compliance with, such restrictions and conditions and the Securities Act of 1933, as amended (the “Securities Act”).

2. We understand that the offer and sale of the Notes have not been registered under the Securities Act, and that the Notes and any interest therein may not be offered or sold except as permitted in the following sentence. We agree, on our own behalf and on behalf of any accounts for which we are acting as hereinafter stated, that if we should sell the Notes or any interest therein, we will do so only (A) to the Issuer or any subsidiary thereof, (B) in accordance with Rule 144A under the Securities Act to a “qualified institutional buyer” (as defined therein), (C) to an institutional “accredited investor” (as defined below) that, prior to such transfer, furnishes (or has furnished on its behalf by a U.S. broker-dealer) to you and to the Issuer a signed letter substantially in the form of this letter and, if such transfer is in respect of a principal amount of Notes, at the time of transfer of less than $250,000, an Opinion of Counsel in form reasonably acceptable to the Issuer to the effect that such transfer is in compliance with the Securities Act, (D) outside the

 

D-3


United States in accordance with Rule 904 of Regulation S under the Securities Act, (E) pursuant to the provisions of Rule 144 under the Securities Act or (F) pursuant to an effective registration statement under the Securities Act, and we further agree to provide to any Person purchasing the Definitive Note or beneficial interest in a Global Note from us in a transaction meeting the requirements of clauses (A) through (E) of this paragraph a notice advising such purchaser that resales thereof are restricted as stated herein.

3. We understand that, on any proposed resale of the Notes or beneficial interest therein, we will be required to furnish to you and the Issuer such certifications, legal opinions and other information as you and the Issuer may reasonably require to confirm that the proposed sale complies with the foregoing restrictions. We further understand that the Notes purchased by us will bear a legend to the foregoing effect.

4. We are an institutional “accredited investor” (as defined in Rule 501(a)(1), (2), (3) or (7) of Regulation D under the Securities Act) and have such knowledge and experience in financial and business matters as to be capable of evaluating the merits and risks of our investment in the Notes, and we and any accounts for which we are acting are each able to bear the economic risk of our or its investment.

5. We are acquiring the Notes or beneficial interest therein purchased by us for our own account or for one or more accounts (each of which is an institutional “accredited investor”) as to each of which we exercise sole investment discretion.

You and the Issuer are entitled to rely upon this letter and are irrevocably authorized to produce this letter or a copy hereof to any interested party in any administrative or legal proceedings or official inquiry with respect to the matters covered hereby.

 

 

[Insert Name of Accredited Investor]

By:

   
 

Name:

 

Title:

 

Dated:    

 

D-4


EXHIBIT E

FORM OF SUPPLEMENTAL INDENTURE

TO BE DELIVERED BY SUBSEQUENT GUARANTORS

[Omitted]


EXHIBIT F to the Indenture

[FORM OF] JUNIOR LIEN INTERCREDITOR AGREEMENT

[Omitted]

Exhibit 10.96

FIRST SUPPLEMENTAL INDENTURE

FIRST SUPPLEMENTAL INDENTURE (this “Supplemental Indenture”), dated as of November 8, 2023, between Venture Global LNG, Inc., a Delaware corporation (the “Issuer”), and The Bank of New York Mellon Trust Company, N.A., as Trustee (in such capacity, the “Trustee”) and Collateral Agent (in such capacity, the “Collateral Agent”) under the Indenture referred to below.

W I T N E S S E T H

WHEREAS, the Issuer has heretofore executed and delivered to the Trustee and the Collateral Agent an indenture (as amended, supplemented or otherwise modified from time to time, the “Indenture”), dated as of October 24, 2023, pursuant to which the Issuer issued $2,500,000,000 aggregate principal amount of the Issuer’s 9.500% Senior Secured Notes due 2029 (the “Initial 2029 Notes”) and $1,500,000,000 aggregate principal amount of the Issuer’s 9.875% Senior Secured Notes due 2032 (the “Initial 2032 Notes” and, together with the Initial 2029 Notes, the “Initial Notes”);

WHEREAS, Section 2.01(e) of the Indenture permits and provides for the issuance of Additional Notes in accordance with and subject to compliance with the provisions of the Indenture, and such Additional Notes shall be consolidated with and form a single class with the Initial Notes and shall have the same terms as the Initial Notes (except for any differences in the issue price, the issue date and the interest accrued, if any);

WHEREAS, the Issuer desires and has requested that the Trustee join it in the execution and delivery of this Supplemental Indenture in connection with the issuance by the Issuer, pursuant to Section 2.01(e) of the Indenture, of an additional $500,000,000 aggregate principal amount of 9.500% Senior Secured Notes due 2029 (the “New 2029 Notes”) and $500,000,000 aggregate principal amount of 9.875% Senior Secured Notes due 2032 (the “New 2032 Notes” and, together with the New 2029 Notes, the “New Notes”);

WHEREAS, Section 9.01(k) of the Indenture provides that the Issuers may from time to time amend the Indenture without the consent of any Holder to provide for the issuance of Additional Notes in accordance with the Indenture;

WHEREAS, the Issuer has provided to the Trustee an Opinion of Counsel and an Officer’s Certificate required by Sections 2.02, 7.02(b), 9.05 and 13.02 of the Indenture;

WHEREAS, all conditions and requirements necessary to issue the New Notes and to make this Supplemental Indenture a valid, binding, and legal instrument in accordance with the terms of the Indenture have been performed and fulfilled and the execution and delivery hereof have been in all respects duly authorized; and

WHEREAS, pursuant to Section 9.01(k) and Section 9.05 of the Indenture, the Trustee and the Collateral Agent are authorized to execute and deliver this Supplemental Indenture.


NOW, THEREFORE, in consideration of the foregoing and for other good and valuable consideration, the receipt of which is hereby acknowledged, the Issuer, the Trustee and the Collateral Agent mutually covenant and agree for the equal and ratable benefit of the Holders as follows:

1. CAPITALIZED TERMS. Capitalized terms used herein without definition shall have the meanings assigned to them in the Indenture.

2. THE ADDITIONAL NOTES. Pursuant to Section 2.01(e) of the Indenture, the Issuer shall issue the New Notes, which are Additional Notes and shall (i) be consolidated with and form a single class with the Initial Notes, and (ii) have the same terms as the Initial Notes (except for any differences in the issue price, the issue date and the interest accrued, if any), as follows:

 

  (a)

General. The New 2029 Notes and the New 2032 Notes shall be evidenced by one or more Global Notes substantially in the form of the Notes attached as Exhibit A-1 and Exhibit A-2, respectively, to the Indenture. For all purposes under the Indenture, the term “Notes” shall include the New Notes.

 

  (b)

Authentication and Delivery of Additional Notes. On the date hereof, $500,000,000 aggregate principal amount of New 2029 Notes and $500,000,000 aggregate principal amount of New 2032 Notes shall be delivered to the Trustee for authentication and delivery. Such New Notes are being issued in accordance with Section 2.02 of the Indenture.

 

  (c)

Issue Date; First Interest Payment. The New Notes shall be issued on November 8, 2023, and shall accrue interest from and including October 24, 2023. The first interest payment date in respect of the New Notes shall be August 1, 2024.

 

  (d)

CUSIP and ISIN. The CUSIP and ISIN numbers for the New Notes shall be as follows:

 

  (i)

New 2029 Notes Rule 144A Global Note: 92332YAC5 and US92332YAC57, respectively;

 

  (ii)

New 2029 Notes Regulation S Temporary Global Note: U9220NAE1 and USU9220NAE14, respectively;

 

  (iii)

New 2032 Notes Rule 144A Global Note: 92332YAD3 and US92332YAD31, respectively; and

 

  (iv)

New 2032 Notes Regulation S Temporary Global Note: U9220NAF8 and USU9220NAF88; respectively.


  (e)

Regulation S Temporary Global Notes and Regulation S Permanent Global Notes. Pursuant to Section 2.01(c) of the Indenture, following the termination of the applicable Restricted Period, the Regulation S Temporary Global Note Legend shall be deemed removed from the Regulation S Temporary Global Note for the New 2029 Notes and the Regulation S Temporary Global Note for the New 2032 Notes, following which temporary beneficial interests in the Regulation S Temporary Global Note for the New 2029 Notes and the Regulation S Temporary Global Note for the New 2032 Notes shall automatically become beneficial interests in the Regulation S Permanent Global Note for the 2029 Notes and the Regulation S Permanent Global Note for the 2032 Notes, respectively, pursuant to the Applicable Procedures. The Issuer may take such further actions as may be reasonably necessary or appropriate (as determined by the Issuer) to cause the beneficial interests in the form of the Regulation S Temporary Global Note for the New 2029 Notes and the Regulation S Temporary Global Note for the New 2032 Notes to be exchanged for beneficial interests in the Regulation S Permanent Global Note for the Initial 2029 Notes and the Regulation S Permanent Global Note for the Initial 2032 Notes, respectively, pursuant to the Applicable Procedures. The aggregate principal amount of any applicable Regulation S Temporary Global Notes and any applicable Regulation S Permanent Global Notes may from time to time be increased or decreased by adjustments made on the records of the Trustee and/or the Paying Agent and the Depositary or their respective nominees, as the case may be, in connection with the foregoing.

3. NO RECOURSE AGAINST OTHERS. No director, officer, employee, incorporator or stockholder of the Issuer, as such, will have any liability for any obligations of the Issuer under the Notes, this Supplemental Indenture, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

4. GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THIS SUPPLEMENTAL INDENTURE AND THE NOTES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

5. EXECUTION; COUNTERPART ORIGINALS. The parties may manually or electronically sign any number of copies of this Supplemental Indenture. Each signed copy will be an original, but all of them together represent the same agreement. The exchange of copies of this Supplemental Indenture and of signature pages by facsimile or electronic format (i.e., “pdf” or “tif”) transmission shall constitute effective execution and delivery of this Supplemental Indenture as to the parties hereto and may be used in lieu of the original Supplemental Indenture for all purposes. Signatures of the parties hereto transmitted by facsimile or electronic format (i.e., “pdf” or “tif”) shall be deemed to be their original signatures for all purposes. Delivery of an executed Supplemental Indenture by one party to any other party may be made by facsimile, electronic mail (including any electronic signature complying with the New York Electronic Signatures and Records Act (N.Y. State Tech. §§ 301-309), as amended from time to time, or other applicable law), including DocuSign, or other transmission method, and the parties hereto agree that any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.


6. EFFECT OF THIS SUPPLEMENTAL INDENTURE. The provisions of this Supplemental Indenture are intended to supplement the Indenture, and the Indenture and this Supplemental Indenture will henceforth be read together. Except as expressly supplemented by this Supplemental Indenture, the Indenture shall continue in full force and effect in accordance with the provisions thereof, and the Indenture (as supplemented and amended by this Supplemental Indenture) is in all respects hereby ratified and confirmed. This Supplemental Indenture and all its provisions shall be deemed a part of the Indenture in the manner and to the extent herein and therein provided and all of the rights, powers, protections and indemnities of each of the Trustee and the Collateral Agent under the Indenture shall apply to this Supplemental Indenture. To the extent of any inconsistency between the terms of the Indenture and this Supplemental Indenture, the terms of this Supplemental Indenture will control. This Supplemental Indenture shall constitute an indenture supplemental to the Indenture and shall be construed in connection with and form a part of the Indenture for all purposes, and every Holder of the Notes heretofore or hereafter authenticated and delivered shall be bound hereby.

7. EFFECT OF HEADINGS. The Section headings herein are for convenience only and shall not affect the construction hereof.

8. THE TRUSTEE AND THE COLLATERAL AGENT. Neither the Trustee nor the Collateral Agent shall be responsible in any manner whatsoever for or in respect of the validity or sufficiency of this Supplemental Indenture or for or in respect of the recitals contained herein, all of which recitals are made solely by the Issuer. Additionally, neither the Trustee nor the Collateral Agent makes any representation as to the validity or sufficiency of this Supplemental Indenture. For the avoidance of doubt, neither the Trustee nor the Collateral Agent, by executing this Supplemental Indenture in accordance with the terms of the Indenture, agrees to undertake additional actions nor does it consent to any transaction beyond what is expressly set forth in this Supplemental Indenture, and each of the Trustee and the Collateral Agent reserves all rights and remedies under the Indenture.

9. PROVISIONS BINDING ON SUCCESSORS. All of the covenants, stipulations, promises and agreements made in this Supplemental Indenture by each of the parties hereto shall bind its successors and assigns whether so expressed or not.


SIGNATURES

Dated as of November 8, 2023

 

VENTURE GLOBAL LNG, INC.

By:

 

/s/ Jonathan W. Thayer

Name:

 

Jonathan W. Thayer

Title:

 

Chief Financial Officer

[Signature page to Supplemental Indenture]


THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee and Collateral Agent
By:   /s/ Terrence T. Rawlins
Name:   Terrence T. Rawlins
Title:   Vice President

[Signature page to SupplementaI Indenture]

Exhibit 10.97

Certain identified information has been omitted from this document because (i) it is not material and is the type that the Company customarily and actually treats as private or confidential, and/or (ii) if disclosure would constitute a clearly unwarranted invasion of personal privacy and has been marked with “[***]” to indicate where omissions have been made.

Execution Version

 

 

 

VENTURE GLOBAL LNG, INC.

AND EACH OF THE GUARANTORS PARTY HERETO FROM TIME TO TIME

7.00% SENIOR SECURED NOTES DUE 2030

 

 

INDENTURE

Dated as of July 24, 2024

 

 

The Bank of New York Mellon Trust Company, N.A.,

as Trustee and Collateral Agent

 

 

 

 

 

 


TABLE OF CONTENTS

ARTICLE 1

DEFINITIONS AND INCORPORATION BY REFERENCE

 

Section 1.01

   Definitions      1  

Section 1.02

   Other Definitions      49  

Section 1.03

   Rules of Construction      50  

Section 1.04

   Limited Condition Transactions      52  

Section 1.05

   Certain Compliance Calculations      53  

Section 1.06

   Acts of Holders      53  

Section 1.07

   Timing of Payment      55  

Section 1.08

   Role of the Collateral Agent      55  

ARTICLE 2

 

THE NOTES

 

 

 

Section 2.01

   Form and Dating      55  

Section 2.02

   Execution and Authentication      56  

Section 2.03

   Registrar and Paying Agent      57  

Section 2.04

   Paying Agent to Hold Money in Trust      57  

Section 2.05

   Holder Lists      58  

Section 2.06

   Transfer and Exchange      58  

Section 2.07

   Replacement Notes      71  

Section 2.08

   Outstanding Notes      71  

Section 2.09

   Treasury Notes      71  

Section 2.10

   Temporary Notes      72  

Section 2.11

   Cancellation      72  

Section 2.12

   Defaulted Interest      72  

ARTICLE 3

 

REDEMPTION AND PREPAYMENT

 

 

 

Section 3.01

   Notices to Trustee      72  

Section 3.02

   Selection of Notes to Be Redeemed      73  

Section 3.03

   Notice of Redemption      73  

Section 3.04

   Effect of Notice of Redemption      75  

Section 3.05

   Deposit of Redemption Price      75  

Section 3.06

   Notes Redeemed or Purchased in Part      75  

Section 3.07

   Optional Redemption      75  

Section 3.08

   Mandatory Redemption; Purchases of Notes      77  

Section 3.09

  

Offer to Purchase by Application of Excess Proceeds

     77  

 

i


ARTICLE 4

COVENANTS

 

Section 4.01

   Payment of Notes      80  

Section 4.02

   Maintenance of Office or Agency      80  

Section 4.03

   Reports      81  

Section 4.04

   Compliance Certificate      83  

Section 4.05

   Taxes      84  

Section 4.06

   Stay, Extension and Usury Laws      84  

Section 4.07

   Limitation on Restricted Payments      84  

Section 4.08

   Limitation on Dividends and Other Payment Restrictions Affecting Restricted Subsidiaries      90  

Section 4.09

   Limitation on Indebtedness, Disqualified Stock and Preferred Equity      93  

Section 4.10

   Limitation on Sales of Assets      99  

Section 4.11

   Limitation on Transactions with Affiliates      103  

Section 4.12

   Limitation on Liens      107  

Section 4.13

   [Reserved]      107  

Section 4.14

   Corporate Existence      107  

Section 4.15

   Offer to Repurchase Upon Change of Control Triggering Event      108  

Section 4.16

   Future Guarantees      109  

Section 4.17

   Designation of Restricted and Unrestricted Subsidiaries      110  

Section 4.18

   Suspension of Certain Covenants      110  

ARTICLE 5

 

SUCCESSORS

 

 

 

Section 5.01

   Merger, Consolidation or Sale of Assets      112  

Section 5.02

   Successor Corporation Substituted      114  

ARTICLE 6

 

DEFAULTS AND REMEDIES

 

 

 

Section 6.01

   Events of Default      115  

Section 6.02

   Acceleration      117  

Section 6.03

   Other Remedies      119  

Section 6.04

   Waiver of Past Defaults      119  

Section 6.05

   Control by Majority      120  

Section 6.06

   Limitation on Suits      120  

Section 6.07

   Rights of Holders of Notes to Receive Payment      120  

Section 6.08

   Collection Suit by Trustee      120  

Section 6.09

   Trustee May File Proofs of Claim      121  

Section 6.10

   Priorities      121  

Section 6.11

   Undertaking for Costs      122  

 

ii


ARTICLE 7

TRUSTEE

 

Section 7.01

   Duties of Trustee      122  

Section 7.02

   Rights of Trustee      123  

Section 7.03

   Individual Rights of Trustee      125  

Section 7.04

   Trustee’s Disclaimer      125  

Section 7.05

   Notice of Defaults      125  

Section 7.06

   Compensation and Indemnity      126  

Section 7.07

   Replacement of Trustee      126  

Section 7.08

   Successor Trustee by Merger, etc      127  

Section 7.09

   Eligibility; Disqualification      128  

Section 7.10

   Security Documents      128  
ARTICLE 8

 

LEGAL DEFEASANCE AND COVENANT DEFEASANCE

 

Section 8.01

   Option to Effect Legal Defeasance or Covenant Defeasance      128  

Section 8.02

   Legal Defeasance and Discharge      128  

Section 8.03

   Covenant Defeasance      129  

Section 8.04

   Conditions to Legal or Covenant Defeasance      129  

Section 8.05

   Deposited Money and Government Securities to be Held in Trust; Other Miscellaneous Provisions      131  

Section 8.06

   Repayment to Issuer      131  

Section 8.07

   Reinstatement      132  
ARTICLE 9

 

AMENDMENT, SUPPLEMENT AND WAIVER

 

Section 9.01

   Without Consent of Holders of Notes      132  

Section 9.02

   With Consent of Holders of Notes      134  

Section 9.03

   Revocation and Effect of Consents      136  

Section 9.04

   Notation on or Exchange of Notes      136  

Section 9.05

   Trustee to Sign Amendments, etc      136  

ARTICLE 10

 

GUARANTEES

 

 

 

Section 10.01

   Guarantee      136  

Section 10.02

   Limitation on Guarantor Liability      137  

Section 10.03

   Execution and Delivery of Guarantee      138  

Section 10.04

   Releases      138  

 

iii


ARTICLE 11

SATISFACTION AND DISCHARGE

 

Section 11.01

   Satisfaction and Discharge      139  

Section 11.02

   Application of Trust Money      140  

ARTICLE 12

 

COLLATERAL AND SECURITY

 

 

 

Section 12.01

   General      141  

Section 12.02

   Security Documents      141  

Section 12.03

   Recording, Registration and Opinions; Trustee’s Disclaimer Regarding Collateral      143  

Section 12.04

   Possession, Use and Release of Collateral      145  

Section 12.05

   Suits to Protect the Collateral      145  

Section 12.06

   Authorization of Receipt of Funds by the Trustee Under the Security Documents      146  

Section 12.07

   Purchaser Protected      146  

ARTICLE 13

 

MISCELLANEOUS

 

 

 

Section 13.01

   Notices      146  

Section 13.02

   Certificate and Opinion as to Conditions Precedent      147  

Section 13.03

   Statements Required in Certificate or Opinion      148  

Section 13.04

   Rules by Trustee and Agents      148  

Section 13.05

   No Personal Liability of Directors, Managers, Officers, Members, Partners, Employees and Equityholders      148  

Section 13.06

   Governing Law; Waiver of Trial by Jury; Jurisdiction      149  

Section 13.07

   No Adverse Interpretation of Other Agreements      149  

Section 13.08

   Successors      149  

Section 13.09

   Severability      150  

Section 13.10

   Execution; Counterpart Originals      150  

Section 13.11

   Table of Contents, Headings, etc      150  

Section 13.12

   Tax Matters      150  

 

iv


EXHIBITS

 

Exhibit A

   FORM OF NOTE DUE 2030

Exhibit B

   FORM OF CERTIFICATE OF TRANSFER

Exhibit C

   FORM OF CERTIFICATE OF EXCHANGE

Exhibit D

   FORM OF CERTIFICATE FROM ACQUIRING INSTITUTIONAL ACCREDITED INVESTOR

Exhibit E

   FORM OF SUPPLEMENTAL INDENTURE

Exhibit F

   FORM OF JUNIOR LIEN INTERCREDITOR AGREEMENT

 

v


INDENTURE dated as of July 24, 2024 among Venture Global LNG, Inc., a Delaware corporation, the guarantors party hereto from time to time and The Bank of New York Mellon Trust Company, N.A., a national banking association, as Trustee and Collateral Agent.

W I T N E S S E T H

WHEREAS, the Issuer has duly authorized the creation of an issue of $1,500,000,000 aggregate principal amount of the Issuer’s 7.00% Senior Secured Notes due 2030 (the “Initial Notes”).

WHEREAS, the Issuer has duly authorized the execution and delivery of this Indenture (as defined herein).

NOW, THEREFORE, the Issuer, the Trustee and the Collateral Agent agree as follows for the benefit of each other and for the equal and ratable benefit of the Holders (as defined herein).

ARTICLE 1

DEFINITIONS AND INCORPORATION BY REFERENCE

Section 1.01 Definitions.

Acquired Debt” means Indebtedness (1) of a Person or any of its Subsidiaries existing at the time such Person becomes a Restricted Subsidiary, (2) assumed in connection with the acquisition of assets from such Person, in each case whether or not incurred by such Person in connection with or in contemplation of such Person becoming a Restricted Subsidiary of the Issuer or such acquisition, or (3) of a Person at the time such Person merges with or into or consolidates or otherwise combines with the Issuer or any Restricted Subsidiary. Acquired Debt will be deemed to have been incurred, with respect to clause (1) of the preceding sentence, on the date such Person becomes a Restricted Subsidiary, with respect to clause (2) of the preceding sentence, on the date of consummation of such acquisition of assets and, with respect to clause (3) of the preceding sentence, on the date of the relevant merger, consolidation or other combination.

Additional Notes” means additional Notes (other than the Initial Notes) issued from time to time under this Indenture in accordance with Section 2.01, Section 2.02, Section 4.09 and Section 4.12 hereof.

Additional Agent” means the administrative agent and/or trustee (as applicable) or any other similar agent, representative or Person under any First Lien Financing Document, in each case, together with its successors and permitted assigns in such capacity.

Additional First Lien Debt Facility” means one or more debt facilities, commercial paper facilities or indentures that are secured equally and ratably with the Notes by the Collateral and whose Senior Class Debt Representative has become a party to an Applicable Intercreditor Agreement in accordance therewith, in each case, as amended, amended and restated, supplemented or otherwise modified, refinanced or replaced from time to time; provided that this Indenture shall not constitute an Additional First Lien Debt Facility at any time.

 

1


Additional First Lien Documents” means, with respect to any series of Additional First Lien Obligations, the notes, credit agreements, indentures, security documents and other operative agreements evidencing or governing such Indebtedness, and each other agreement entered into for the purpose of securing any series of Additional First Lien Obligations, as the same may be amended, restated, supplemented or otherwise modified from time to time.

Additional First Lien Obligations” means, with respect to any Additional First Lien Debt Facility and including, for the avoidance of doubt, the Existing Notes Obligations, (a) all principal of and interest (including, without limitation, any interest that accrues after the commencement of any case, proceeding or other action relating to the bankruptcy, insolvency or reorganization of the Issuer or any Guarantor, whether or not allowed or allowable as a claim in any such proceeding) payable with respect to such Additional First Lien Debt Facility, (b) all other amounts payable to the related Additional First Lien Secured Parties under the related Additional First Lien Documents and (c) any renewals or extensions of the foregoing.

Additional First Lien Secured Parties” means, with respect to any series of Additional First Lien Obligations, the holders of such Additional First Lien Obligations, the Additional Agent with respect thereto, any trustee or agent or any other similar agent or Person therefor under any related Additional First Lien Documents and the beneficiaries of each indemnification obligation undertaken by the Issuer or any Guarantor under any related Additional First Lien Documents.

Affiliate” means, with respect to any specified Person, any other Person directly or indirectly controlling or controlled by or under direct or indirect common control with such specified Person.

For the purposes of this definition, “control,” when used with respect to any specified Person, means the power to direct or cause the direction of the management and policies of such Person, directly or indirectly, whether through the ownership of voting securities, by contract or otherwise; and the terms “controlling” and “controlled” have meanings correlative to the foregoing.

Agent” means the Collateral Agent, any Registrar, co-registrar, Paying Agent or additional paying agent in respect of the Notes.

Applicable Intercreditor Agreement” means, as the context may require, the First Lien Intercreditor Agreement and/or the Junior Lien Intercreditor Agreement, or any Market Intercreditor Agreement or another intercreditor agreement (which may, if applicable consist of a collateral proceeds “waterfall”).

applicable law” means, except as the context may otherwise require, all applicable laws (including common law), rules, regulations, ordinances, judgments, decrees, injunctions, writs and orders of any Governmental Authority.

Applicable Procedures” means, with respect to any transfer or exchange of or for, redemption of, or notice with respect to beneficial interests in any Global Note or the redemption or repurchase of any Global Note, the rules and procedures of DTC and/or the Depositary that apply to such transfer, exchange, redemption or repurchase.

 

2


Applicable Redemption Premium” means, with respect to any Note on any redemption date, the greater of:

(1) 1.0% of the principal amount of the Note; and

(2) the excess of:

(A) the present value at such redemption date of (x) the redemption price of such Note at January 15, 2027 (such redemption price being set forth in Section 3.07(c)), plus (y) all required remaining scheduled interest payments due on such Note through January 15, 2027, excluding accrued but unpaid interest to, but excluding, the redemption date and computed using a discount rate equal to the Treasury Rate as of such redemption date plus 50 basis points; over

(B) the outstanding principal amount of the Note,

as calculated by the Issuer or an agent appointed by the Issuer. For the avoidance of doubt, calculations of the Applicable Redemption Premium shall not be a duty or obligation of the Trustee, the Collateral Agent, the Registrar or any Paying Agent or any other Agent.

Asset Sale” means:

(1) the sale, lease, transfer, conveyance or other disposition of any assets by the Issuer or any of its Restricted Subsidiaries (including by way of a Sale and Leaseback Transaction) outside of the ordinary course of business; provided, however, that the sale, lease, transfer, conveyance or other disposition of all or substantially all of the assets of the Issuer and its Restricted Subsidiaries taken as a whole will be governed by Section 4.15 and/or Section 5.01 and not by Section 4.10; and

(2) the issuance of Equity Interests by any Restricted Subsidiary or the sale by the Issuer or any of its Restricted Subsidiaries of Equity Interests in any of the Restricted Subsidiaries (in each case, other than directors’ qualifying shares).

Notwithstanding the preceding, none of the following items will be deemed to be an Asset Sale:

(1) any single transaction or series of related transactions that involves assets having a Fair Market Value of less than the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period;

(2) a transfer of assets or Equity Interests between or among the Issuer and any Restricted Subsidiary, except to the extent such assets or Equity Interests constitutes or would constitute Collateral unless such assets or Equity Interests would continue to constitute Collateral following such transfer or would constitute Excluded Capital Stock following such transfer;

(3) an issuance of Equity Interests by a Restricted Subsidiary to the Issuer or to a Restricted Subsidiary;

 

3


(4) the sale, lease or other transfer of accounts receivable, inventory or other assets in the ordinary course of business, and any sale or other disposition of damaged, worn-out, surplus or obsolete assets or assets that are no longer useful in the conduct of the business of the Issuer and its Restricted Subsidiaries or economically practicable or commercially reasonable to maintain, in each case whether now owned or hereafter acquired, in each case in in the good faith determination of the Issuer;

(5) the sale, conveyance or other disposition for value of environmental attributes or energy, fuel, water or emission credits or similar rights or contracts for any of the foregoing by the Issuer or any of its Restricted Subsidiaries;

(6) licenses and sublicenses by the Issuer or any of its Restricted Subsidiaries;

(7) any surrender or waiver of contract rights or settlement, release, recovery on or surrender of contract, tort or other claims;

(8) the granting and enforcement and exercise of a Lien not prohibited by Section 4.12, and any sale, transfer or other disposition in connection therewith or deemed reasonably necessary or desirable by the Issuer in good faith for the consummation thereof;

(9) any Restricted Payment not prohibited by Section 4.07 or the proceeds of which are substantially contemporaneously used to fund a Permitted Investment or the making of a Restricted Payment not prohibited by Section 4.07, or any Permitted Investment;

(10) the sale or other disposition of cash or Cash Equivalents;

(11) the disposition of receivables in connection with the compromise, settlement or collection thereof in bankruptcy or similar proceedings;

(12) the foreclosure, condemnation, expropriation, forced dispositions, eminent domain or any similar action with respect to any property or other assets, transfers of any property that have been subject to a casualty to the respective insurer of such property as part of an insurance settlement or upon receipt of the net proceeds of such casualty event, or a surrender or waiver of contract rights or the settlement, release or surrender of contract, tort or other claims of any kind;

(13) the disposition of assets to a person who is providing services (the provision of which has been or is to be outsourced by the Issuer or any Subsidiary to such person) related to such assets;

(14) the lease (including Sale and Leaseback Transactions and inverted lease transactions), as lessor or sublessor, or license (other than any long-term exclusive license), as licensor or sublicensor, of real or personal property or intellectual property that does not materially interfere with the business of the Issuer and its Restricted Subsidiaries, taken as a whole;

 

4


(15) Sale and Leaseback Transactions, as lessee or sublessee, and other dispositions by a Non-Recourse Subsidiary in connection with Non-Recourse Financing incurred by such Non-Recourse Subsidiary;

(16) the cancellation of intercompany Indebtedness with the Issuer or any of its Restricted Subsidiaries permitted under this Indenture;

(17) swaps of assets for other similar assets or assets whose value is reasonably equivalent or greater in terms of type, value and quality, than the assets being swapped, as determined in good faith by the Issuer;

(18) the unwinding or termination of Hedging Obligations;

(19) the issuance, sale or other disposition of Equity Interests in (i) Joint Ventures or (ii) Subsidiaries, substantially all of which Subsidiaries’ or Joint Ventures’ assets are assets that, if disposed of separately, would not constitute an Asset Sale, in a single transaction or series of related transactions;

(20) dispositions of investments in Joint Ventures to the extent required by, or made pursuant to buy/sell and/or put/call arrangements between the Joint Venture parties set forth in, Joint Venture agreements and similar binding arrangements;

(21) the issuance of Equity Interests by the Issuer or a Restricted Subsidiary to the holders of its Equity Interests in accordance with the charter, partnership agreement, limited liability company agreement or other governing documents of such Person;

(22) the issuance, sale or other disposition of Equity Interests or other assets of a Non-Recourse Subsidiary; provided that any Net Proceeds of such disposition are (A) applied to Project Costs of the Project to which such Non-Recourse Subsidiary relates or to repay a Non-Recourse Financing of such Project or (B) applied in accordance with Section 4.10(b)(1);

(23) any sale, lease, conveyance or other disposition of Equity Interests in, or Indebtedness or other securities of, an Unrestricted Subsidiary;

(24) dispositions of improvements made to leased real property to landlords pursuant to customary terms of leases entered into in the ordinary course of business;

(25) the lapse or abandonment of intellectual property rights (including any registrations or applications therefor) in the ordinary course of business or consistent with industry practice, which in the reasonable good faith determination of the Issuer, are not material to the conduct of the business of the Issuer and its Subsidiaries, taken as a whole;

(26) any sale, transfer or other disposition to effect the formation of any Subsidiary that is a Delaware Divided LLC; provided that upon formation of such Delaware Divided LLC, such Delaware Divided LLC shall be a Restricted Subsidiary;

 

5


(27) any sale, transfer or other disposition in connection with, and deemed reasonably necessary or desirable by the Issuer in good faith for the consummation of, any IPO Reorganization Transactions or any Tax Restructuring;

(28) Permitted Intercompany Activities and related transactions;

(29) any Equity Financing Transaction;

(30) ECR Transactions; and

(31) (A) dispositions or discounts without recourse of accounts receivable, notes receivable, rights to payment, other current assets or participations therein, or (B) dispositions of assets in connection with any Permitted Receivables Financing Assets pursuant to any Permitted Receivables Financing (including Equity Interests in any Subsidiary all of substantially all of the assets of which are Permitted Receivables Financing Assets).

In the event that a transaction (or a portion thereof) meets the criteria of a permitted Asset Sale and would also be a permitted Restricted Payment or Permitted Investment, the Issuer, in its sole discretion, will be entitled to divide and classify such transaction (or a portion thereof) as an Asset Sale and/or one or more of the types of permitted Restricted Payments or Permitted Investments.

Asset Sale Prepayment Percentage” means 100%; provided that if, at the time of receipt by the Issuer or the relevant Restricted Subsidiary of the Net Proceeds from any Asset Sale (or at any time during the applicable reinvestment period described herein), on a pro forma basis after giving effect to the applicable Asset Sale and the application of the Net Proceeds therefrom, (i) the Holdco Debt Ratio is less than or equal to 0.95 to 1.00 and greater than 0.70 to 1.00, such percentage shall instead be 50% or (ii) the Holdco Debt Ratio is less than or equal to 0.70 to 1.00, such percentage shall instead be 0%.

Bank Product Obligations” means all obligations and liabilities of any kind, nature or character (whether direct or indirect, absolute or contingent, liquidated or unliquidated, voluntary or involuntary, due or to become due that are in existence on the Issue Date or thereafter incurred) of the Issuer or any Restricted Subsidiary, whether on account of principal, interest, reimbursement obligations, fees, indemnities, costs, expenses or otherwise, which may arise under, out of, or in connection with any treasury, investment, depository, clearing house, wire transfer, commercial credit card, purchasing card, merchant card, cash management or automated clearing house transfers of funds services or any related services, including all renewals, extensions and modifications thereof and all costs, attorneys’ fees and expenses incurred by a holder of Bank Product Obligations in connection with the collection or enforcement thereof.

Bankruptcy Code” means Title 11 of the United States Code (11 U.S.C. § 101 et seq.), as amended.

Bankruptcy Law” means the Bankruptcy Code and any other state or federal insolvency, reorganization, moratorium or similar law for the relief of debtors.

 

6


Beneficial Owner” has the meaning assigned to such term in Rule 13d-3 and Rule 13d-5 under the Exchange Act. The terms “Beneficially Owns,” “Beneficially Owned” and “Beneficial Ownership” have a corresponding meaning.

Board of Directors” means:

(1) with respect to a corporation, the board of directors of the corporation (including any committee thereof duly authorized to act on behalf of such board);

(2) with respect to a partnership having only one general partner, the board of directors of the general partner of the partnership;

(3) with respect to a limited liability company, the managing member or members or any controlling committee of managing members or other governing body thereof; and

(4) with respect to any other Person, the board or committee of such Person serving a similar function.

Business Day” means a day other than a Saturday, Sunday or other day on which banking institutions in New York or a place of payment under this Indenture are authorized or required by law to close.

Capital Stock” means:

(1) in the case of a corporation or company, corporate stock or shares;

(2) in the case of an association or business entity, any and all shares, interests, participations, rights or other equivalents (however designated) of corporate stock;

(3) in the case of a partnership or limited liability company, partnership interests (whether general or limited) or membership interests; and

(4) any other interest or participation that confers on a Person the right to receive a share of the profits and losses of, or distributions of assets of, the issuing Person, but excluding from all of the foregoing any debt securities convertible into Capital Stock, whether or not such debt securities include any right of participation with Capital Stock.

Captive Insurance Subsidiary” means (a) any Subsidiary of the Issuer operating for the purpose of (i) insuring the businesses, operations or properties owned or operated by any Parent Entity, the Issuer or any of its Subsidiaries, including their future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members), and related benefits and/or (ii) conducting any activities or business incidental thereto (it being understood and agreed that activities which are relevant or appropriate to qualify as an insurance company for U.S. federal or state tax purposes shall be considered “activities or business incidental thereto”) or (b) any Subsidiary of any such insurance subsidiary operating for the same purpose described in clause (a) above.

 

7


Cash Equivalents” means, as at any date of determination, any of the following: (i) marketable securities (a) issued or directly and unconditionally guaranteed as to interest and principal by the United States government or (b) issued by any agency of the United States the obligations of which are backed by the full faith and credit of the United States, in each case maturing within one year after such date; (ii) marketable direct obligations issued by any state of the United States of America or any political subdivision of any such state or any public instrumentality thereof, in each case maturing within one year after such date and having, at the time of the acquisition thereof, a rating of at least A-1 from S&P or at least P-1 from Moody’s; (iii) commercial paper maturing no more than three months from the date of creation thereof and having, at the time of the acquisition thereof, a rating of at least A-1 from S&P or at least P-1 from Moody’s; (iv) certificates of deposit or bankers’ acceptances maturing within three months after such date and issued or accepted by any lender or by any commercial bank organized under the laws of the United States of America or any state thereof or the District of Columbia that (a) is at least “adequately capitalized” (as defined in the regulations of its primary Federal banking regulator) and (b) has Tier 1 capital (as defined in such regulations) of not less than $1,000,000,000; and (v) shares of any money market mutual fund that (a) has substantially all of its assets invested continuously in the types of investments referred to in clauses (i) and (ii) above, (b) has net assets of not less than $5,000,000,000, and (c) has the highest rating obtainable from either S&P or Moody’s.

Change of Control” means the occurrence of any of the following:

(1) the consummation of any transaction (including, without limitation, any merger or consolidation) the result of which is that any “person” or “group” of related persons (as such terms are used in Section 13(d)(3) of the Exchange Act) other than any of the Permitted Holders, becomes the beneficial owner (as such term is defined in Rules 13d- 3 and Rule 13d-5 under the Exchange Act), directly or indirectly, of more than 50% of the voting power of the Voting Stock of the Issuer (or its successors by merger, consolidation or purchase of all or substantially all of its assets); or

(2) the direct or indirect sale, lease, transfer, conveyance or other disposition (other than by way of merger or consolidation), in one or a series of related transactions, of all or substantially all of the properties or assets of the Issuer and its Subsidiaries taken as a whole to any “person” (as such term is used in Section 13(d)(3) of the Exchange Act) other than any of the Permitted Holders;

provided, however, that a transaction in which the Issuer becomes a Subsidiary of another Person (other than any of the Permitted Holders) shall not constitute a Change of Control if (a) the shareholders of the Issuer immediately prior to such transaction Beneficially Own, directly or indirectly through one or more intermediaries, at least a majority of the voting power of the outstanding Voting Stock of the Issuer immediately following the consummation of such transaction or (b) immediately following the consummation of such transaction, no “person” (as such term is defined above), other than such other Person (but including the holders of the Equity Interests of such other Person) and/or any of the Permitted Holders, Beneficially Owns, directly or indirectly through one or more intermediaries, more than 50% of the voting power of the outstanding Voting Stock of the Issuer; provided further, (i) a Person or group shall not be deemed to Beneficially

 

8


Own Voting Stock subject to an equity or asset purchase agreement, merger agreement, option agreement, warrant agreement or similar agreement (or voting or option or similar agreement related thereto) until the consummation of the acquisition of Voting Stock in connection with the transactions contemplated by such agreement, (ii) the phrase “person” or “group” is within the meaning of Section 13(d) or 14(d) of the Exchange Act, but excluding (A) any employee benefit plan of such Person or “group” and its subsidiaries and any Person acting in its capacity as trustee, agent or other fiduciary or administrator of any such plan and (B) any underwriter in connection with an IPO, and (iii) if any group includes one or more Permitted Holders, the issued and outstanding Voting Stock of the Issuer or the IPO Entity Beneficially Owned, directly or indirectly, by any Permitted Holders that are part of such group shall not be treated as being Beneficially Owned by such “group” or any other member of such group for purposes of determining whether a Change of Control has occurred.

Change of Control Triggering Event” means the occurrence of both a Change of Control and a Rating Decline.

Clearstream” means Clearstream Banking, S.A.

Code” means the United States Internal Revenue Code of 1986, as amended from time to time, and any successor statute thereto.

Collateral” means, unless released in accordance with the terms of this Indenture or the Collateral Agency Agreement and subject to the occurrence of any Reversion Date, all assets and properties subject to Liens created pursuant to the Security Documents to secure the Note Obligations and the other First Lien Obligations (other than any Excluded Asset); provided that, with respect to any cash or cash equivalents (i) collateralizing letters of credit obligations under, or (ii) deposited in a debt service reserve account relating to, in each case, one series of First Lien Obligations, such collateral shall only be for the benefit of the particular First Lien Secured Parties who issued or have participation interests in such letters of credit or such First Lien Obligations.

Collateral Agency Agreement” means the Collateral Agency Agreement dated as of May 26, 2023 among the Issuer, each other Grantor (as defined and referred to therein), the trustee for the Existing Notes, each other Senior Class Debt Representative from time to time party thereto and the Collateral Agent, as it may be amended, amended and restated, supplemented or otherwise modified from time to time.

Collateral Agent” has the meaning ascribed to such term in the Collateral Agency Agreement.

Commission” means the U.S. Securities and Exchange Commission.

continuing” means, with respect to any Default or Event of Default, that such Default or Event of Default has not been cured or waived.

Contractual Obligation” means as to any Person, any provision of any security issued by such Person or any obligation under any contract, agreement, instrument or other written undertaking to which such Person is a party or by which it or any of its property is bound.

 

9


Controlled Investment Affiliate” means, as to any Person, any other Person, which directly or indirectly is in control of, is controlled by, or is under common control with such Person and is organized by such Person (or any Person controlling such Person) primarily for making direct or indirect equity or debt investments in the Issuer and/or other companies.

Corporate Trust Office of the Trustee” means the address of the Trustee at 601 Travis Street, 16th floor, Houston, TX 770021 or such other address as to which the Trustee may give notice to the Issuer.

Credit Facilities” means one or more debt facilities, credit agreements, commercial paper facilities, note purchase agreements, indentures, or other agreements, in each case with banks, lenders, purchasers, investors, trustees, agents or other representatives of any of the foregoing, providing for revolving credit loans, term loans, receivables financing (including through the sale of receivables or interests in receivables to such lenders or other Persons or to special purpose entities formed to borrow from such lenders or other Persons against such receivables or sell such receivables or interests in receivables), or letters of credit, notes, earn-out obligations constituting Indebtedness or other borrowings or other extensions of credit, including any notes, mortgages, guarantees, collateral documents, instruments and agreements executed in connection therewith, in each case, as amended, restated, modified, renewed, refunded, restated, restructured, increased, supplemented, replaced or refinanced in whole or in part from time to time, including any replacement, refunding or refinancing facility or agreement that increases the amount permitted to be borrowed thereunder or alters the maturity thereof or adds entities as additional borrowers or guarantors thereunder and whether by the same or any other agent, lender group of lenders, counterparties or otherwise.

Cumulative Distributable Cash” means, with respect to any date of determination, the cumulative Distributable Cash for the period (taken as one accounting period) from, and including, the first day of the fiscal quarter in which the Reference Date occurs, to, and including, the end of the most recently ended fiscal quarter of the Issuer for which internal financial statements are available as of such date of determination.

Custodian” means the Trustee, as custodian with respect to the Global Notes, or any successor entity thereto.

Default” means any event that is, or with the passage of time or the giving of notice or both would be, an Event of Default.

Definitive Note” means a certificated Note registered in the name of the Holder thereof, issued in accordance with Section 2.06, substantially in the form of Exhibit A except that such Note shall not bear the Global Note Legend and shall not have the “Schedule of Exchanges of Interests in the Global Note” attached thereto.

Delaware Divided LLC” means any Delaware LLC formed upon the consummation of a Delaware LLC Division.

 

1 

NTD: Trustee to confirm address.

 

10


Delaware LLC” means any limited liability company organized or formed under the laws of the State of Delaware.

Delaware LLC Division” means the statutory division of any Delaware LLC into two or more Delaware LLCs pursuant to Section 18-217 of the Delaware Limited Liability Company Act.

Derivative Instruments” with respect to a Person, means any contract, instrument or other right to receive payment or delivery of cash or other assets to which such Person or any Affiliate of such Person that is acting in concert with such Person in connection with such Person’s investment in the Notes (other than a Screened Affiliate) is a party (whether or not requiring further performance by such Person), the value and/or cash flows of which (or any material portion thereof) are materially affected by the value and/or performance of the Notes and/or the creditworthiness of the Issuer.

Depositary” means, with respect to the Notes issuable or issued in whole or in part in global form, any Person specified in Section 2.03 hereof as the Depositary with respect to the Notes, and any and all successors thereto appointed as Depositary hereunder and having become such pursuant to the applicable provision of this Indenture.

Designated Non-cash Consideration” means the fair market value of non-cash consideration received by the Issuer or a Restricted Subsidiary in connection with an Asset Sale that is so designated as Designated Non-cash Consideration pursuant to an Officer’s Certificate, setting forth the basis of such valuation, executed by the principal financial officer of the Issuer, less the amount of cash or Cash Equivalents received in connection with a subsequent sale of or collection on such Designated Non-cash Consideration. A particular item of Designated Non-Cash Consideration will no longer be considered to be outstanding when and to the extent it has been paid, redeemed or otherwise retired or sold or otherwise disposed of in exchange for consideration in the form of Cash Equivalents in compliance with Section 4.10.

Designated Preferred Stock” means Preferred Stock of the Issuer or any Parent Entity (in each case other than Disqualified Stock) that is issued for cash (other than to a Restricted Subsidiary or an employee stock ownership plan or trust established by the Issuer or any of its Subsidiaries) and is so designated as Designated Preferred Stock, pursuant to an Officer’s Certificate, on the issuance date thereof, the cash proceeds of which are excluded from any calculation of Incremental Funds.

Disqualified Stock” means, with respect to any Person, any Capital Stock of such Person that, by its terms (or by the terms of any security into which it is convertible or for which it is puttable or exchangeable, either mandatorily or at the option of the holder thereof), or upon the happening of any event or condition matures or is mandatorily redeemable (other than solely for Capital Stock of such Person or any Parent Entity thereof that would not otherwise constitute Disqualified Stock, and for cash in lieu of fractional shares of Capital Stock and other than solely as a result of a change of control, asset sale, casualty, condemnation or eminent domain) pursuant to a sinking fund obligation or otherwise, or is redeemable at the option of the holder thereof (other than solely for Capital Stock of such Person or as a result of a change of control, asset sale, casualty, condemnation or eminent domain), in whole or in part, in each case prior to the date 91 days after the earlier of the maturity date of the Notes or the date the Notes are no longer outstanding;

 

11


provided, however, that if such Capital Stock is issued to any future, current or former employee, director, officer, manager or consultant (or their respective Controlled Investment Affiliates or Immediate Family Members), of the Issuer, any of its Subsidiaries, any Parent Entity or any other entity in which the Issuer or a Restricted Subsidiary has an Investment and is designated in good faith as an “affiliate” by the Board of Directors of the Issuer (or the compensation committee thereof) or any other plan for the benefit of current, former or future employees (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or its Subsidiaries or by any such plan to such employees (or their respective Controlled Investment Affiliates or Immediate Family Members), such Capital Stock shall not constitute Disqualified Stock solely because it may be required to be repurchased by the Issuer or its Subsidiaries in order to satisfy applicable statutory or regulatory obligations.

Distributable Cash” means, for any period, the aggregate amount of net cash provided by (used in) operating activities of the Issuer and its Subsidiaries for such period, determined on a consolidated basis in accordance with GAAP, adjusted as follows (in each case, without duplication):

 

  (a)

decreased by the aggregate amount of net cash provided by (used in) operating activities of any Unrestricted Subsidiaries of the Issuer for such period; and

 

  (b)

increased by the sum of the following:

 

  (i)

the aggregate amount of any scheduled cash interest payments and any other debt service payments with respect to any Indebtedness of the Issuer and its Restricted Subsidiaries, solely to the extent such payments are actually made during such period using net cash provided by financing activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (ii)

the aggregate amount of any Test Revenue to the extent included in net cash provided by (used in) investing activities of the Issuer and its Restricted Subsidiaries for such period, determined on a consolidated basis in accordance with GAAP; plus

 

  (iii)

the aggregate amount of dividends, distributions or return on investment actually received by the Issuer or any of its Restricted Subsidiaries during such period in the form of cash or Cash Equivalents from any Person that is not a Restricted Subsidiary (including any Unrestricted Subsidiary, Joint Venture or investment recorded in such Person under the equity method of accounting); plus

 

  (iv)

solely to the extent Distributable Cash is used to determine the Fixed Charge Coverage Ratio, the aggregate amount of any operating expenses incurred by the Issuer during such period; and

 

12


  (c)

decreased by the sum of the following:

 

  (i)

the aggregate amount of any scheduled cash interest payments, amortization payments and any other debt service payments and repayments with respect to any Non-Recourse Financing of any Non-Recourse Subsidiary, solely to the extent such payments are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (ii)

the aggregate amount of any cash distributions or cash repurchase amounts actually paid during such period to any Person (other than the Issuer and its Restricted Subsidiaries) with respect to any Disqualified Stock or Preferred Equity issued by, or non-controlling interest in, any Non-Recourse Subsidiary, solely to the extent such distributions or repurchases are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (iii)

the aggregate amount of any mandatory payments actually made during such period with respect to any ECR Transaction, solely to the extent such payments are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; plus

 

  (iv)

the aggregate amount of any Investments actually made by the Issuer or any of its Restricted Subsidiaries during such period in the form of cash or Cash Equivalents in any Person that is not a Restricted Subsidiary (including any Unrestricted Subsidiary, Joint Venture or Investment recorded in such Person under the equity method of accounting), solely to the extent such Investments are actually made during such period using net cash provided by operating activities of the Issuer and its Restricted Subsidiaries for such period; and

 

  (d)

decreased by deposits into (or increased by withdrawals from) any restricted cash accounts during such period that are required pursuant to any Non-Recourse Financing of any Non-Recourse Subsidiary (including fully funding any contingency requirements, reserving for remaining construction costs and fulfilling any debt service reserve account obligations), solely to the extent that such deposits (or withdrawals) decrease (or increase) net cash provided by (used in) operating activities of the Issuer and its Restricted Subsidiaries for such period.

Early Cargo Revenues” means, with respect to any group of Project Companies for an applicable Project, the total cash permitted to be distributed by such group of Project Companies to the Issuer prior to the applicable commercial operation date under the Non-Recourse Financing for the applicable Project.

ECR Transaction” means any transaction involving the use of Early Cargo Revenues (and no other funds of a Recourse Person) to provide credit support (contingent or otherwise), equitize or otherwise finance any Project Company in connection with a Non-Recourse Financing or Equity Financing Transaction; provided that, no Person that benefits from such ECR Transaction shall have recourse to any Recourse Person other than rights to Early Cargo Revenues actually received by any Recourse Person and (for the avoidance of doubt) shall not be entitled to any Lien on the assets of any Recourse Person.

 

13


Electronic Means” means any of the following communications methods: e-mail, secure electronic transmission containing applicable authorization codes, passwords and/or authentication keys issued by the Trustee, or another method or system specified by the Trustee as available for use in connection with its services hereunder.

Equity Financing Transaction” means any bona fide equity issuance or equity financing transaction or series of related transactions by any Non-Recourse Subsidiary (including, for the avoidance of doubt, any issuance or series of related issuances of Disqualified Stock, Preferred Equity or other Equity Interests by any Non-Recourse Subsidiary) (a) the proceeds of which are used for the financing (or refinancing) of all or any portion of any Project to which such Non- Recourse Subsidiary relates, all or any portion of any other Project Costs relating to any such Project, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith; provided that, to the extent such Disqualified Stock, Preferred Equity of other Equity Interests are issued by a Non-Recourse Subsidiary that is an obligor under any Non-Recourse Financing relating to the applicable Project, the proceeds of the issuance of such Disqualified Stock, Preferred Equity of other Equity Interests may be used for the purpose of, or in connection with, any financing (or refinancing) of all or any portion of any one or more other Projects, all or any portion of any Project Costs relating to any such one or more other Projects, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith, so long as such use of proceeds is permitted under the terms of each Non-Recourse Financing that is then outstanding to which such Non-Recourse Subsidiary is a party (and not pursuant to an amendment or waiver of any such Non-Recourse Financing in contemplation thereof); and (b) such transaction or series of related transactions does not result in such Non-Recourse Subsidiary no longer constituting a “Restricted Subsidiary” for purposes of this Indenture immediately after giving effect thereto.

Equity Interests” means Capital Stock and all warrants, options or other rights to acquire Capital Stock (but excluding any debt security that is convertible into, or exchangeable for, Capital Stock).

Equity Offerings” means any public or private sale after the Issue Date of Capital Stock of the Issuer or any Parent Entity (including an IPO), the proceeds of which have been contributed to the Issuer as common equity, other than (i) public offerings with respect to the Issuer’s common stock registered on Form S-4 or Form S-8; and (ii) issuances to the Issuer or any Subsidiary of the Issuer.

Euroclear” means Euroclear Bank, S.A./N.V.

Exchange Act” means the U.S. Securities Exchange Act of 1934, as amended, or any successor statute, and the rules and regulations promulgated by the Commission thereunder.

 

14


Excluded Assets” means (a) any asset (including any general intangibles and any contract, instrument, lease, license, permit, agreement or other document, or any property or other right subject thereto (including pursuant to a purchase money security interest, capital lease or similar arrangement or, in the case of after-acquired property, pre-existing secured Indebtedness not incurred in anticipation of the acquisition by the Issuer or any Guarantor of such property)) the grant or perfection of a security interest in which would (i) constitute a violation of a restriction in favor of a third party (other than the Issuer, any Guarantor or any Subsidiary thereof) or result in the abandonment, invalidation or unenforceability of any right or assets of the Issuer or the relevant Guarantor, as applicable, (ii) result in a breach, termination (or a right of termination) or default under any such contract, instrument, lease, license, permit, agreement or other document (including pursuant to any “change of control” or similar provision) (there being no requirement pursuant to any Note Document to obtain any consent in respect thereof from any Person that is not also the Issuer, a Guarantor or any Subsidiary thereof) or (iii) permit any Person (other than the Issuer, any Guarantor or any Subsidiary thereof) to amend any rights, benefits and/or obligations of the Issuer or the relevant Guarantor, as applicable, in respect of such relevant asset or permit such Person to require the Issuer, any Guarantor or any Subsidiary thereof to take any action materially adverse to the interests of such Subsidiary, the Issuer or Guarantor; provided, however, that any such asset will only constitute an Excluded Asset under clause (i) or clause (ii) above to the extent such violation or breach, termination (or right of termination) or default would not be rendered ineffective pursuant to Sections 9-406, 9-407, 9-408 or 9-409 of the UCC (or any successor provision or provisions) of any relevant jurisdiction or any other applicable requirement of law; provided, further, that any such asset shall cease to constitute an Excluded Asset at such time as the condition causing such violation, breach, termination (or right of termination) or default or right to amend or require other actions no longer exists and to the extent severable, the security interest granted under the applicable Security Document shall attach immediately to any portion of such general intangible or other right that does not result in any of the consequences specified in clauses (i) through (iii) above, (b) Excluded Capital Stock, (c) any intent-to-use (or similar) trademark application prior to the filing of a “Statement of Use,” “Amendment to Allege Use” or similar filing with respect thereto, only to the extent, if any, that, and solely during the period, in which, if any, the grant of a security interest therein may impair the validity or enforceability, or result in the voiding of, such intent-to-use trademark application or any registration issuing therefrom under applicable law, (d) any asset or property (including Capital Stock), the grant or perfection of a security interest in which would (A) require any governmental or regulatory consent, approval, license or authorization (there being no requirement under any Note Document to obtain the consent of any Governmental Authority or other Person (other than the Issuer, any Guarantor or any Subsidiary thereof), including, without limitation, no requirement to comply with the Federal Assignment of Claims Act or any similar statute), unless such consent, approval, license or authorization has been obtained, (B) be prohibited or restricted by applicable requirements of law (including enforceable anti-assignment provisions of applicable requirements of law), except, in the case of the foregoing clause (A) and this clause (B), to the extent such prohibition would be rendered ineffective under applicable anti-assignment provisions of the UCC of any relevant jurisdiction notwithstanding such prohibition, (C) trigger termination of any contract pursuant to a “change of control” or similar provision and is binding on such asset on the Issue Date or at the time of its acquisition and not incurred in contemplation thereof; it being understood that “Excluded Assets” shall not include proceeds or receivables arising out of any contract described in this clause (d) to the extent that the assignment of such proceeds or receivables is expressly deemed to be effective under the UCC or any other applicable law notwithstanding the relevant provision or (D) result in material adverse tax consequences to the Issuer, any Guarantor or any

 

15


Subsidiary thereof, as determined by the Issuer in good faith, (e) (i) except to the extent a security interest therein can be perfected by the filing of a UCC financing statement, any leasehold interest and (ii) any real property or real property interest, (f) any margin stock, (g) any governmental or regulatory license or state or local franchise, charter, consent, permit or authorization to the extent the granting of a security interest therein is prohibited or restricted thereby or by applicable requirements of law, other than the proceeds thereof, the assignment of which is expressly deemed effective under the UCC notwithstanding such prohibition; provided, however, that any such asset will only constitute an Excluded Asset under this clause (g) to the extent such prohibition or restriction would not be rendered ineffective pursuant to applicable anti-assignment provisions of the UCC of any relevant jurisdiction, (h) any letter of credit right (other than to the extent a security interest in such letter of credit right can be perfected by filing an “all-assets” UCC financing statement) and all commercial tort claims, (i) any cash or Cash Equivalents (other than cash and Cash Equivalent representing identifiable proceeds of other Collateral, a security interest in which can be perfected through the filing of an “all-assets” UCC financing statement), (j) any deposit account or commodity or securities account (excluding any securities entitlements and any related assets to the extent a security interest therein can be perfected through the filing of an “all assets” UCC financing statement; it being understood that this exception does not apply to cash or Cash Equivalents other than cash and Cash Equivalents representing identifiable proceeds of other Collateral), (k) any motor vehicle, airplane or other asset subject to a certificate of title (other than to the extent a security interest therein can be perfected by filing an “all assets” UCC financing statement and without the requirement to list any VIN, serial or similar number), (l) any asset with respect to which the Collateral Agent and the Issuer or the relevant Guarantor, as applicable, have reasonably determined that the cost, burden, difficulty or consequence (including any effect on the ability of the Issuer or the relevant Guarantor, as applicable, to conduct its operations and business in the ordinary course of business) of obtaining or perfecting a security interest therein outweighs the benefit of a security interest to the relevant Notes Parties afforded thereby and (m) except for the Issuer, all assets and property of any other Person other than Pledged Equity and the proceeds thereof.

Excluded Capital Stock” means the Capital Stock of any Subsidiary of the Issuer that is (i) not a Wholly-Owned Subsidiary directly owned by the Issuer or any Guarantor, (ii) an Immaterial Subsidiary or (iii) an Unrestricted Subsidiary.

Existing 2028 Notes” means the aggregate principal amount of the Issuer’s 8.125% Senior Secured Notes due 2028 outstanding on the Issue Date.

Existing 2029 Notes” means the aggregate principal amount of the Issuer’s 9.500% Senior Secured Notes due 2029 outstanding on the Issue Date.

Existing 2031 Notes” means the aggregate principal amount of the Issuer’s 8.375% Senior Secured Notes due 2031 outstanding on the Issue Date.

Existing 2032 Notes” means the aggregate principal amount of the Issuer’s 9.875% Senior Secured Notes due 2032 outstanding on the Issue Date.

 

16


Existing Indebtedness” means any Indebtedness, Disqualified Stock and Preferred Stock of the Issuer and its Restricted Subsidiaries (other than the Notes, the Guarantees and Indebtedness that constitutes Non-Recourse Financing that is incurred by a Non-Recourse Subsidiary) outstanding on the Issue Date.

Existing Indentures” means (i) the Existing May 2023 Indenture and (ii) the Existing October 2023 Indenture.

Existing May 2023 Indenture” means the indenture, dated as of May 26, 2023, among the Issuer and The Bank of New York Mellon Trust Company, N.A., as trustee and collateral agent, and the guarantors from time to time party thereto, governing the Existing 2028 Notes and the Existing 2031 Notes, as amended, supplemented or modified from time to time.

Existing Notes” means the Existing 2028 Notes, the Existing 2029 Notes, the Existing 2031 Notes and the Existing 2032 Notes.

Existing Notes Documents” means the Existing Indentures (including any guarantees), the Existing Notes and the Security Documents.

Existing Notes Obligations” means all obligations of the Issuer and the guarantors under the Existing Indentures (including any guarantees), the Existing Notes and the Security Documents.

Existing Notes Parties” means, collectively, the trustee for the holders of the Existing Notes, the collateral agent, each other agent, and the holders of the Existing Notes, in each case, under the Existing Indentures.

Existing October 2023 Indenture” means the indenture, dated as of October 24, 2023, among the Issuer and The Bank of New York Mellon Trust Company, N.A., as trustee and collateral agent, and the guarantors from time to time party thereto, governing the Existing 2029 Notes and the Existing 2032 Notes, as amended, supplemented or modified from time to time.

Fair Market Value” means the value that would be paid by a willing buyer to an unaffiliated willing seller in a transaction not involving distress of either party, as determined by the Issuer in good faith.

Finance Lease Obligations” means an obligation that is required to be classified and accounted for as a finance lease for financial reporting purposes on the basis of GAAP. The amount of such obligation will be the capitalized amount of such obligation at the time any determination thereof is to be made as determined on the basis of GAAP.

First Lien Financing Document” means (i) the Notes Documents, (ii) the Existing Notes Documents and (iii) each Additional First Lien Document.

First Lien Intercreditor Agreement” means the first lien intercreditor agreement, dated as of September 28, 2023, among the trustee for the holders of the Existing Notes, the Collateral Agent and the senior class debt representatives from time to time party thereto, and acknowledged by the Company and the other grantors from time to time party thereto, as amended, supplemented or modified from time to time.

 

17


First Lien Obligations” means (i) the Note Obligations, (ii) the Existing Notes Obligations and (iii) any Additional First Lien Obligations.

First Lien Secured Parties” means (i) the Collateral Agent, (ii) the Notes Parties, (iii) the Existing Notes Parties and (iv) the Additional First Lien Secured Parties with respect to each series of Additional First Lien Obligations.

Fixed Charge Coverage Ratio” means as of any date of determination, the ratio of: (x) the aggregate amount of Distributable Cash for the applicable Test Period plus the aggregate amount of Fixed Charges for the applicable Test Period to (y) the aggregate amount of the Fixed Charges for the applicable Test Period. In the event that the Issuer or any Restricted Subsidiary (other than any Non-Recourse Subsidiary) incurs, assumes, guarantees, redeems, repays, retires or extinguishes any Indebtedness (other than Indebtedness incurred or repaid under any revolving credit facility unless such Indebtedness has been permanently repaid and has not been replaced) or issues or redeems Disqualified Stock or Preferred Equity subsequent to the commencement of the period for which the Fixed Charge Coverage Ratio is being calculated but prior to or simultaneously with the event for which the calculation of the Fixed Charge Coverage Ratio is made (the “Calculation Date”), then the Fixed Charge Coverage Ratio shall be calculated giving pro forma effect to such incurrence, assumption, guarantee, redemption, repayment, defeasance, discharge, retirement or extinguishment of Indebtedness, or such issuance or redemption of Disqualified Stock or Preferred Equity, as if the same had occurred at the beginning of the applicable four-quarter period.

In addition, for purposes of making the computation referred to above,

(1) Investments, acquisitions, dispositions, mergers, amalgamations, consolidations and discontinued operations (as determined in accordance with GAAP) that have been made by the Issuer or any of its Subsidiaries during the Test Period or subsequent to such Test Period and on or prior to or simultaneously with the Calculation Date shall be calculated on a pro forma basis assuming that all such Investments, acquisitions, dispositions, mergers, amalgamations, consolidations and discontinued operations (and the change in any associated fixed charge obligations and the change in Distributable Cash resulting therefrom) had occurred on the first day of the Test Period;

(2) if since the beginning of the Test Period, any Person that subsequently became a Subsidiary or was merged with or into the Issuer or any of its Subsidiaries since the beginning of such period shall have made any Investment, acquisition, disposition, merger, amalgamation, consolidation or discontinued operation that would have required adjustment pursuant to this definition, then the Fixed Charge Coverage Ratio shall be calculated giving pro forma effect thereto for such period as if such Investment, acquisition, disposition, merger, amalgamation, consolidation or discontinued operation had occurred at the beginning of the applicable Test Period;

(3) any Person that is a Restricted Subsidiary or a Subsidiary on the Calculation Date will be deemed to have been a Restricted Subsidiary or a Subsidiary, as applicable, at all times during the applicable Test Period, and any Person that is not a Restricted Subsidiary or a Subsidiary on the Calculation Date will be deemed not to have been a Restricted Subsidiary or a Subsidiary, as applicable, at any time during the Test Period;

 

18


(4) if any Indebtedness bears a floating rate of interest, the interest expense on such Indebtedness will be calculated as if the rate in effect on the Calculation Date had been the applicable rate for the entire period (taking into account any Hedging Obligation applicable to such Indebtedness);

(5) interest on a Finance Lease Obligation shall be deemed to accrue at an interest rate reasonably determined by a responsible financial or accounting officer of the Issuer to be the rate of interest implicit in such Finance Lease Obligation in accordance with GAAP; and

(6) interest on Indebtedness that may optionally be determined at an interest rate based upon a factor of a prime or similar rate, a eurocurrency interbank offered rate, or other rate, shall be deemed to have been based upon the rate actually chosen, or, if none, then based upon such optional rate chosen as the Issuer may designate.

For purposes of this definition, whenever pro forma effect is to be given to an acquisition or disposition of assets, the amount of income or earnings relating thereto and the amount of Fixed Charges associated with any Indebtedness incurred in connection therewith, the pro forma calculations shall be determined in good faith by the Issuer (and may include, for the avoidance of doubt, cost savings, operating expense reductions and synergies resulting from such Investment, acquisition, disposition, merger, amalgamation, consolidation, discontinued operation, operational change, business expansion or other transaction which is being given pro forma effect).

Fixed Charges” means, for any period, without duplication, the sum of:

(1) consolidated interest expense of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) for such period including, with respect to the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) (a) amortization of original issue discount resulting from the issuance of Indebtedness at less than par, (b) all commissions, discounts and other fees and charges owed with respect to letters of credit, bank guarantees or bankers acceptances, (c) the interest component of Finance Lease Obligations, and (d) net payments, if any made (less net payments, if any, received), pursuant to interest rate Hedging Obligations with respect to Indebtedness, but excluding (i) annual agency fees paid to the administrative agents and collateral agents under any credit facilities, (ii) costs associated with obtaining Hedging Obligations and breakage costs in respect of Hedging Obligations related to interest rates, (iii) penalties and interest relating to taxes, (iv) amortization or expensing of deferred financing fees, amendment and consent fees, debt issuance costs, commissions, fees and expenses and discounted liabilities, (v) any expensing of bridge, commitment and other financing fees and any other fees related to any acquisitions, (vi) commissions, discounts, yield and other fees and charges (including any interest expense) related to any Permitted Receivables Financing, (vii) any accretion of accrued interest on discounted liabilities and any prepayment premium or penalty, (viii) any interest expense attributable to obligations of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) that are classified as “capital lease obligations” under GAAP due to the consolidation of variable interest entities and (ix) any “additional interest” or “liquidated damages” with respect to other securities for failure to timely comply with registration rights obligations ; plus

 

19


(2) cash dividends on any Disqualified Stock or Preferred Equity of the Issuer or any Restricted Subsidiary (other than Non-Recourse Subsidiaries), provided that any Disqualified Stock of the Issuer or any Restricted Subsidiary (other than Non-Recourse Subsidiaries) and any Preferred Equity of any Restricted Subsidiary (other than Non-Recourse Subsidiaries) is incurred in accordance with Section 4.09, plus

(3) consolidated capitalized interest of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) for such period, whether paid or accrued.

For purposes of this definition, interest on a Finance Lease Obligation shall be deemed to accrue at an interest rate reasonably determined by such Person to be the rate of interest implicit in such Finance Lease Obligation in accordance with GAAP.

GAAP” means generally accepted accounting principles in the United States of America as in effect from time to time; provided, that if any such accounting principle changes after the Issue Date, the Issuer may, at its option, elect to employ such accounting principle or (2) if elected by the Issuer by written notice to the Trustee in any accounting principles that are recognized as being generally accepted as set forth above which are in effect from time to time, in each case as in effect on the first date of the period for which the Issuer makes such an election and thereafter as in effect from time to time; provided that in each case any such election, once made, shall be irrevocable. Notwithstanding any other provision contained in this Indenture, the amount of any Indebtedness under GAAP with respect to Finance Lease Obligations shall be determined in accordance with the definition of “Finance Lease Obligations.”

Global Note Legend” means the legend set forth in Section 2.06(g)(2), which is required to be placed on all Global Notes issued under this Indenture.

Global Notes” means, individually and collectively, each of the Restricted Global Notes, the Unrestricted Global Notes and any Additional Notes issued as a Global Note, substantially in the form attached as Exhibit A, deposited with or on behalf of and registered in the name of the Depositary or its nominee, issued in accordance with Section 2.01 and Section 2.06.

Governmental Authority” means the government of the United States or any other nation, or of any political subdivision thereof, whether state or local, and any agency, authority, instrumentality, regulatory body, court, central bank or other entity exercising executive, legislative, judicial, taxing, regulatory or administrative powers or functions of or pertaining to government.

Government Securities” means direct obligations of, or obligations guaranteed by, the United States of America (including any agency or instrumentality thereof) for the payment of which obligations or guarantees the full faith and credit of the United States of America is pledged and which are not callable or redeemable at the issuer’s option.

 

20


guarantee” means a guarantee other than by endorsement of negotiable instruments for collection or deposit in the ordinary course of business, of all or any part of any Indebtedness (whether arising by agreements to keep-well, to take or pay or to maintain financial statement conditions, pledges of assets or otherwise).

Guarantee” means any guarantee of the Issuer’s obligations under this Indenture and the Notes by any Restricted Subsidiary in accordance with the provisions of this Indenture. When used as a verb, “Guarantee” shall have a corresponding meaning.

Guarantors” means any Restricted Subsidiary that executes a Guarantee in accordance with the provisions of this Indenture, and their respective successors and assigns.

Hedging Obligations” means, with respect to any specified Person, the obligations of such Person under:

(1) currency exchange, interest rate or commodity swap agreements, currency exchange, interest rate or commodity cap agreements and currency exchange, interest rate or commodity collar agreements; and

(2) (i) agreements or arrangements designed to protect such Person against fluctuations in currency exchange, interest rates, commodity prices or commodity transportation or transmission pricing or availability; (ii) any netting arrangements, purchase and sale agreements for renewable energy credits, fuel purchase and sale agreements, swaps, options and other agreements entered into for hedging purposes, in each case, that fluctuate in value with fluctuations in energy, power or gas prices; and (iii) agreements or arrangements for commercial or trading activities with respect to the purchase, transmission, distribution, sale, lease or hedge of any energy related commodity or service.

Holdco Total Debt” means, as of any date, the sum of (1) the aggregate amount of all outstanding Indebtedness of the Issuer and its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) on a consolidated basis consisting of Indebtedness for borrowed money, Finance Lease Obligations, purchase money obligations and debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit (but excluding any Non-Recourse Financing and Permitted Receivables Financings), plus (2) the aggregate amount of all outstanding Disqualified Stock of the Issuer and Disqualified Stock and Preferred Stock of its Restricted Subsidiaries (other than Non-Recourse Subsidiaries) on a consolidated basis, with the amount of such Disqualified Stock or Preferred Stock, as applicable, equal to the greater of its voluntary or involuntary liquidation preference and its Maximum Fixed Repurchase Prices, determined on a consolidated basis in accordance with GAAP, as calculated with such pro forma adjustments as are appropriate and consistent with the pro forma adjustment provisions set forth in the definition of “Fixed Charge Coverage Ratio.” For purposes hereof, the “Maximum Fixed Repurchase Price” of any Disqualified Stock or Preferred Stock means the price at which such Disqualified Stock or Preferred Stock could be redeemed or repurchased by the issuer thereof in accordance with its terms or, if such Disqualified Stock or Preferred Stock cannot be so redeemed or repurchased, the fair market value of such Disqualified Stock or Preferred Stock (as determined in good faith by the Issuer), determined on any date on which Holdco Total Debt shall be required to be determined.

 

21


Holdco Debt Ratio” means, for any Test Period, the ratio of (1) Holdco Total Debt as of the end of such Test Period to (2) Distributable Cash for such Test Period, in each case with such pro forma adjustments to Holdco Total Debt and Distributable Cash as are appropriate, in each case as calculated with such pro forma adjustments as are appropriate and consistent with the pro forma adjustment provisions set forth in the definition of “Fixed Charge Coverage Ratio,” as determined in good faith by the Issuer.

Holder” means a Person in whose name a Note is registered.

IAI Global Note” means a Global Note other than a Regulation S Global Note or a Rule 144A Global Note, issued in connection with a transfer of a Note or an interest therein to an Institutional Accredited Investor in reliance on an exemption from the registration requirements of the Securities Act.

Immaterial Subsidiary” means, as of any date, any Restricted Subsidiary that does not have consolidated assets in excess of 5.0% of consolidated total assets of the Issuer and its Restricted Subsidiaries as of the last day of the applicable Test Period; provided that, the consolidated total assets (as so determined) of all Immaterial Subsidiaries shall not exceed 10.0% of consolidated total assets of the Issuer and its Restricted Subsidiaries as of the last day of the applicable Test Period; provided, further, that, any direct Wholly-Owned Subsidiary of the Issuer that owns, directly or indirectly, all or a portion of the Calcasieu Pass Project, the TransCameron pipeline, the Plaquemines Project, the Gator Express pipeline, the CP2 Project, the CP Express pipeline, the Delta Project and/or the Delta Express pipeline shall not, in any event, be an Immaterial Subsidiary.

Immediate Family Members” means, with respect to any individual, such individual’s child, stepchild, grandchild or more remote descendant, parent, stepparent, grandparent, spouse, former spouse, qualified domestic partner, sibling, mother-in-law, father-in-law, son-in-law and daughter-in-law (including adoptive relationships, the estate of such individual and such other individuals above) and any trust, partnership or other bona fide estate-planning vehicle the only beneficiaries of which are any of the foregoing individuals or any private foundation or fund that is controlled by any of the foregoing individuals or any donor-advised fund of which any such individual is the donor.

Indebtedness” means, with respect to any specified Person, any indebtedness of such Person (excluding accrued expenses and trade payables, except as provided in clause (5) below), whether or not contingent:

(1) in respect of borrowed money;

(2) evidenced by bonds, notes, debentures or similar instruments or letters of credit (or reimbursement agreements in respect thereof);

(3) in respect of banker’s acceptances;

(4) representing Finance Lease Obligations in respect of sale and leaseback transactions;

 

22


(5) obligations representing the balance of deferred and unpaid purchase price of any property or services with a scheduled due date more than six months after such property is acquired or such services are completed; or

(6) representing the net amount owing under any Hedging Obligations,

if and to the extent any of the preceding items (other than letters of credit and Hedging Obligations) would appear as a liability upon a balance sheet of the specified Person prepared in accordance with GAAP.

In addition, the term “Indebtedness” includes all Indebtedness of others secured by a Lien on any asset of the specified Person (whether or not such Indebtedness is assumed by the specified Person) and, to the extent not otherwise included, the guarantee by the specified Person of any Indebtedness of any other Person; provided that the amount of such Indebtedness shall be deemed not to exceed the lesser of the amount secured by such Lien and the value of the Person’s property securing such Lien.

For the avoidance of doubt and notwithstanding the foregoing, the term “Indebtedness” will not include: (i) non-interest bearing installment obligations, contingent obligations and accrued liabilities, in each case that are incurred in the ordinary course of business and are not more than 90 days past due; (ii) obligations (a) in respect of any acquisition or contribution agreement with respect to any Permitted Investment (other than obligations constituting Indebtedness pursuant to clause (5) of this definition), or (b) existing by virtue of rights of a Non- Recourse Subsidiary under a Project Obligation collaterally assigned to a creditor, which rights may be exercised pursuant to such Project Obligation against the Issuer or any Restricted Subsidiary that is party to such Project Obligation, (iii) any prepayments or deposits received from customers or obligations in respect of funds held on behalf of customers (including, without limitation, in relation to periodic purchase volume or sales incentive rebates), in each case, in the ordinary course of business, (iv) any obligations under any license, permit or approval or guarantees thereof incurred prior to the Issue Date in the ordinary course of business, (v) in connection with the purchase by the Issuer or any Restricted Subsidiary of any business or project, any post-closing payment adjustments to which the seller may become entitled to the extent such payment is determined by a final closing balance sheet or such payment depends on the performance of such business after the closing (other than obligations constituting Indebtedness pursuant to clause (5) of this definition); provided, however, that, at the time of closing, the amount of any such payment is not determinable and, to the extent such payment thereafter becomes fixed and determined, the amount is paid in a timely manner; and (vi) any Capital Stock.

Indenture” means this indenture, as amended, supplemented or otherwise modified from time to time.

Indirect Participant” means a Person who holds a beneficial interest in a Global Note through a Participant.

Initial Notes” has the meaning assigned to it in the recitals to this Indenture.

 

23


Initial Purchasers” means BofA Securities, Inc., MUFG Securities Americas Inc., Santander US Capital Markets LLC, SMBC Nikko Securities America, Inc., Loop Capital Markets LLC, ING Financial Markets LLC, RBC Capital Markets, LLC, Scotia Capital (USA) Inc., Mizuho Securities USA LLC, J.P. Morgan Securities LLC, Goldman Sachs & Co. LLC, BBVA Securities Inc., Natixis Securities Americas LLC, ICBC Standard Bank Plc, Deutsche Bank Securities Inc., Wells Fargo Securities, LLC, National Bank of Canada Financial Inc., R. Seelaus & Co., LLC, Raymond James & Associates, Inc., DZ Financial Markets LLC and Regions Securities LLC.

Institutional Accredited Investor” means an institution that is an “accredited investor” as defined in Rule 501(a)(1), (2), (3) or (7) under the Securities Act, who are not also QIBs.

Interest Payment Date” means January 15 and July 15 of each year, beginning on January 15, 2025.

Investment” means, with respect to any Person, all direct or indirect investments by such Person in other Persons in the forms of loans (including guarantees or other obligations), advances or capital contributions, purchases or other acquisitions for consideration of Indebtedness, Equity Interests or other securities.

For purposes of Section 4.07, “Investment” will include the portion (proportionate to the Issuer’s equity interest in a Restricted Subsidiary to be designated as an Unrestricted Subsidiary) of the Fair Market Value of the net assets of such Restricted Subsidiary of the Issuer at the time that such Restricted Subsidiary is designated an Unrestricted Subsidiary; provided, however, that upon a redesignation of such Subsidiary as a Restricted Subsidiary, the Issuer will be deemed to continue to have a permanent “Investment” in an Unrestricted Subsidiary in an amount (if positive) equal to (a) the Issuer’s “Investment” in such Subsidiary at the time of such redesignation less (b) the portion (proportionate to the Issuer’s equity interest in such Subsidiary) of the Fair Market Value of the net assets of such Subsidiary at the time that such Subsidiary is so re-designated a Restricted Subsidiary.

Investment Grade Rating” means: (a) with respect to S&P, any of the categories from and including AAA to and including BBB- (or equivalent successor categories); (b) with respect to Moody’s, any of the categories from and including Aaa to and including Baa3 (or equivalent successor categories); and (c) with respect to Fitch, any of the categories from and including AAA to and including BBB- (or equivalent successor categories).

Investors” means (a) the VGP Investor, (b) the Management Investors and (c) other holders of Equity Interests in the Issuer or VG Inc. on the Issue Date.

Issue Date” means July 24, 2024.

Issuer” means Venture Global LNG, Inc., and any and all successors thereto.

IPO” means (a) the issuance by the Issuer or any Parent Entity of common Equity Interests in an underwritten public offering (other than a public offering pursuant to a registration statement on Form S-8 or comparable filing in any other applicable jurisdiction) pursuant to an effective registration statement filed with the Commission or any other comparable Governmental Authority in any other applicable jurisdiction or pursuant to Rule 144A (whether as a primary offering, a secondary public offering or a combination thereof) and (b) any other transaction or series of related transactions (including any acquisition by, or combination or other similar transaction with,

 

24


a special purpose acquisition company that (i) is an entity organized or existing under the laws of the U.S., any state thereof or the District of Columbia, (ii) prior to the IPO engaged in no material business or activity other than those related to becoming and acting as a special purpose acquisition company and consummating the IPO and (iii) immediately prior to the IPO had no material assets other than cash and Cash Equivalents) that results in any of the common Equity Interests of the Issuer or any Parent Entity being publicly traded on any U.S. national securities exchange or over-the-counter market or any analogous exchange or market.

IPO Reorganization Transactions” means, collectively, the transactions effected in connection with and reasonably related to consummating an IPO.

Joint Venture” means any Person that is not a direct or indirect Subsidiary of the Issuer in which the Issuer or any of its Restricted Subsidiaries makes any Investment.

Junior Lien Obligations” means the obligations with respect to Indebtedness permitted to be incurred under this Indenture, which is by its terms intended to be secured by a Lien on the Collateral that is junior to the Lien on the Collateral that secures the Notes and the Guarantees; provided such Lien is not prohibited by the terms of this Indenture; provided, further, that (i) the holders of such Indebtedness, or the representative of such holders, shall become party to an Applicable Intercreditor Agreement and any other applicable intercreditor agreements, in each case, agreeing to be bound thereby and (ii) the Issuer has designated such Indebtedness as “Junior Lien Obligations” under such Applicable Intercreditor Agreement.

Junior Lien Representative” means in the case of any Junior Lien Obligations incurred after the Issue Date, the trustee, administrative agent, collateral agent, security agent or similar agent under the credit agreement, indenture or other operative documents governing such Junior Lien Obligations that is named as the representative in respect of such Junior Lien Obligations in the Junior Lien Intercreditor Agreement or joinder thereto.

Junior Lien Secured Parties” means with respect to any Junior Lien Obligation, all lenders, holders, trustees or agents to which such Junior Lien Obligations are owing.

Lien” means, with respect to any asset:

(1) any mortgage, deed of trust, deed to secure debt, lien (statutory or otherwise), pledge, hypothecation, encumbrance, restriction, collateral assignment, charge or security interest in, on or of such asset;

(2) the interest of a vendor or a lessor under any conditional sale agreement, capital lease or title retention agreement (or any financing lease having substantially the same economic effect as any of the foregoing) relating to such asset; and

(3) in the case of Equity Interests or debt securities, any purchase option, call or similar right of a third party with respect to such Equity Interests or debt securities.

 

25


“Limited Condition Transaction” means the entering into or consummation of any transaction (including any Restricted Payment, Change of Control, acquisition (whether by merger, consolidation or other business combination or the acquisition of capital stock, Indebtedness or otherwise) or other Investment by the Issuer or one or more of its Restricted Subsidiaries).

Long Derivative Instruments” means, as to any person, a Derivative Instrument (i) the value of which to such person generally increases, and/or the payment or delivery obligations of such person under which generally decrease, with positive changes in the financial performance and/or position of the Issuer and/or (ii) the value of which to such person generally decreases, and/or the payment or delivery obligations of such person under which generally increase, with negative changes in the financial performance and/or position of the Issuer.

Management Advances” means loans or advances made to, or guarantees with respect to loans or advances made to, directors, officers, employees or consultants (or their respective Controlled Investment Affiliates or Immediate Family Members) of any Parent Entity, the Issuer or any Restricted Subsidiary:

(1) (a) in respect of travel, entertainment, relocation or moving related expenses, payroll advances, deferred compensation and other analogous or similar expenses or payroll expenses, in each case incurred in the ordinary course of business or consistent with past practice or industry norms, or in connection with any Investment or acquisition (by meter, consolidation, amalgamation or otherwise) that is not prohibited by this Indenture, or (b) for purposes of funding any such Person’s purchase or redemption of Capital Stock (or similar obligations) of the Issuer, its Subsidiaries or any Parent Entity that is not prohibited by Section 4.07;

(2) in respect of relocation or moving related expenses, payroll advances and other analogous or similar expenses or payroll expenses, in each case incurred in connection with any closing or consolidation of any facility or office; or

(3) not exceeding $10 million in the aggregate outstanding at the time of incurrence.

Management Investors” means any individual who is a future, current or former officer, director, manager, member, member of management, employee, consultant or independent contractor of the Issuer, any Subsidiary or any Parent Entity who are (directly or indirectly through one or more investment vehicles) holders of Equity Interests in the Issuer and/or any Parent Entity and their Permitted Transferees.

Market Capitalization” means an amount equal to (i) the total number of issued and outstanding shares of common Capital Stock of the Issuer or any Parent Entity on the date of the declaration of a Restricted Payment permitted pursuant to Section 4.07(b)(20) multiplied by (ii) the arithmetic mean of the closing prices per share of such common Capital Stock on the principal securities exchange on which such common Capital Stock is traded for the 30 consecutive trading days immediately preceding the date of declaration of such Restricted Payment.

Market Intercreditor Agreement” means an intercreditor or subordination agreement or arrangement (which may take the form of a “waterfall” or similar provision) the terms of which are (a) consistent with market terms governing intercreditor arrangements for the sharing or subordination of Liens or arrangements relating to the distribution of payments in respect of

 

26


Collateral, as applicable, at the time the applicable agreement or arrangement is proposed to be established in light of the type of Indebtedness subject thereto or (b) in the event an Intercreditor Agreement has been entered into after the Issue Date, the terms of which are, taken as a whole, not materially less favorable to the holders of the Notes than the terms of such Intercreditor Agreement to the extent such agreement governs similar priorities, in each case of clauses (a) and (b) as determined by the Issuer in good faith.

Net Proceeds” means the aggregate cash proceeds received by the Issuer or any of its Restricted Subsidiaries in respect of any Asset Sale (including, without limitation, any cash received upon the sale or other disposition of any non-cash consideration or Cash Equivalents substantially concurrently received in any Asset Sale), net of (i) the direct costs relating to such Asset Sale, including, without limitation, legal, accounting and investment banking fees, and sales commissions, and any relocation expenses incurred as a result of the Asset Sale, (ii) all Taxes paid or reasonably estimated to be payable as a result of the Asset Sale, (iii) all distributions and other payments required to be made to minority interest holders (other than the Issuer or any Subsidiary) in Subsidiaries or Joint Ventures as a result of such Asset Sale, (iv) all payments made on any Indebtedness which is secured by any assets subject to such Asset Sale, in accordance with the terms of any Lien upon such assets, provided that if such Indebtedness is revolving Indebtedness the related commitments are terminated, or which by applicable law are required to be repaid out of the proceeds from such Asset Sale, (v) any funded escrow established pursuant to the documents evidencing such sale or disposition to secure and indemnification obligation on adjustments to the purchase price associated with any such Asset Sale, and (vi) any reserve against liabilities associated with such Asset Sale, including pension and other post-employment benefit liabilities, liabilities related to environmental matters and indemnification obligations associated with such Asset Sale, with any subsequent reduction of the reserve other than by payments made and charged against the reserved amount to be deemed a receipt of cash.

Net Short” means, with respect to a holder or beneficial owner, as of a date of determination, either (i) the value of its Short Derivative Instruments exceeds the sum of (x) the value of its Notes plus (y) the value of its Long Derivative Instruments as of such date of determination or (ii) it is reasonably expected that such would have been the case were a Failure to Pay or Bankruptcy Credit Event (each as defined in the 2014 ISDA Credit Derivatives Definitions) to have occurred with respect to the Issuer immediately prior to such date of determination.

Non-Recourse Financing” means any Indebtedness (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness):

(1) as to which no Recourse Person provides any guarantee or other credit support (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness) or is directly or indirectly liable (as a guaranteeing person or otherwise) or has granted a Lien on any of its assets as security (or has any obligation, contingent or otherwise, to do so), other than, in each case, (i) customary carve-out matters for which a Recourse Person acts as a guarantor in connection with such Indebtedness, such as, without limitation, fraud, misappropriation, breach of representation and warranty and misapplication, (ii) any guarantees or other credit support of such Indebtedness by a Recourse Person made pursuant to Section 4.09(a) or that would

 

27


otherwise constitute Permitted Debt, in each case, so long as such Recourse Person becomes a Guarantor to the extent required under Section 4.16, (iii) any Permitted Project Undertakings, (iv) any guarantees or other credit support in connection with any ECR Transaction, (v) any Standard Securitization Undertakings, and (vi) any Permitted Intercompany Activities; and

(2) which is incurred by one or more Non-Recourse Subsidiaries (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness) for the purpose of, or in connection with, any financing (or refinancing) of all or any portion of any Project to which such Non-Recourse Subsidiaries relate, all or any portion of any Project Costs relating to any such Project, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith; provided that, to the extent such Non-Recourse Financing is incurred by a Non-Recourse Subsidiary that is an obligor under any Non-Recourse Financing relating to the applicable Project that is not structurally or otherwise subordinated or junior to any other Non-Recourse Financing for such Project, the proceeds of such Non-Recourse Financing being incurred may be used for the purpose of, or in connection with, any financing (or refinancing) of all or any portion of any one or more other Projects, all or any portion of any Project Costs relating to any such one or more other Projects, and/or any activities reasonably related or ancillary thereto or necessary, appropriate or desirable in connection therewith, in each case as determined by the Issuer in good faith, so long as such use of proceeds is permitted under the terms of each Non-Recourse Financing that is then outstanding in respect of the Project to which such Non-Recourse Subsidiary is a party (and not pursuant to an amendment or waiver of any such Non-Recourse Financing in contemplation thereof).

Non-Recourse Subsidiary” means each of the following, as determined at any time and from time to time by the Issuer in good faith:

(1) any Restricted Subsidiary of the Issuer that (i) is a Project Company, (ii) has no Subsidiaries and owns no material businesses or assets other than those Subsidiaries, businesses and assets reasonably necessary, appropriate or desirable for, or reasonably related or ancillary to, no more than one individual Project or other activities reasonably related or ancillary thereto, or necessary, appropriate or desirable in connection therewith, and (iii) has no Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit then outstanding other than any Non-Recourse Financing, Indebtedness arising from Permitted Intercompany Activities or otherwise between or among the Issuer and any Restricted Subsidiaries not prohibited by this Indenture, and guarantees of Indebtedness of any other Person (other than the Issuer or any Restricted Subsidiary) that are otherwise not prohibited by this Indenture; and

(2) any Restricted Subsidiary of the Issuer that (i) is the direct or indirect owner of all or a majority (including together with one or more other Non-Recourse Subsidiaries) of the Equity Interests in one or more Persons, each of which meets the qualifications set forth in clause (1) of this definition, (ii) has no Subsidiaries other than Subsidiaries each of which meets the conditions set forth in clause (1) or clause (2)(i) of this definition, (iii)

 

28


owns no material businesses or assets other than those businesses and assets reasonably necessary, appropriate or desirable for, or reasonably related or ancillary to, no more than one individual Project or other activities reasonably related or ancillary thereto, or necessary, appropriate or desirable in connection therewith, and (iv) has no Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit then outstanding other than any Non-Recourse Financing, Indebtedness arising from Permitted Intercompany Activities or otherwise between or among the Issuer and any Restricted Subsidiaries not prohibited by this Indenture, and guarantees of Indebtedness of any other Person (other than the Issuer or any Restricted Subsidiary) that are otherwise not prohibited by this Indenture.

As of the Issue Date, each of Venture Global Calcasieu Pass Holding, LLC, Calcasieu Pass Funding, LLC, Calcasieu Pass Holdings, LLC, Calcasieu Pass Pledgor, LLC, Venture Global Calcasieu Pass, LLC, TransCameron Pipeline, LLC, Calcasieu Tug Services, LLC, Calcasieu Pass Operations, LLC, TransCameron Operations, LLC, Venture Global CCS Cameron, LLC, Venture Global Plaquemines LNG Holding II, LLC, Venture Global Plaquemines LNG Holding, LLC, Plaquemines LNG Funding, LLC, Plaquemines LNG Holdings Pledgor, LLC, Plaquemines LNG Holdings, LLC, Plaquemines LNG Pledgor, LLC, Venture Global Plaquemines LNG, LLC, Venture Global Gator Express, LLC, Plaquemines Tug Services, LLC, Plaquemines LNG Operations, LLC, Venture Global CCS Plaquemines, LLC, Gator Express Operations, LLC, Venture Global CP2 LNG Holding, LLC, Venture Global CP2 LNG, LLC, Venture Global CP Express, LLC, Venture Global Delta LNG, LLC, Venture Global Delta Express, LLC, Venture Global Midstream Holdings, LLC, VG LNG Shipping, LLC, CP2 LNG Operations, LLC, CP Express Operations, LLC, Cameron Generation, LLC, Plaquemines Generation, LLC, Venture Global Ship Management Ltd., Venture Global Shipping Holdings, LLC, Venture Global Shipping I, LLC, Venture Global Shipping II, LLC, Venture Global Shipping III, LLC, Venture Global Shipping IV, LLC, Venture Global Shipping V, LLC, Venture Global Shipping Holdings, LLC, Astra 5 Limited, Venture Global CP3 LNG, LLC, Blackfin Pipeline Holdings, LLC, Blackfin Pipeline, LLC, Blackfin Supply, LLC, Venture Global Land Holdings, LLC, HQ 1001 19 North Holdings, LLC, HQ 1001 19 NORTH, LLC and VG LNG Shipping, LLC shall constitute Non- Recourse Subsidiaries.

“Non-U.S. Person” means a Person who is not a U.S. Person.

Note Documents” means this Indenture (including any Guarantee), the Notes and the Security Documents.

Note Obligations” means all obligations of the Issuer and the Guarantors under the Note Documents.

Notes” means the Initial Notes and any Additional Notes. Unless the context requires otherwise, all references to “Notes” for all purposes of this Indenture shall include any Additional Notes that are actually issued and authenticated. The Initial Notes and all Additional Notes shall be treated as a single class for all purposes under this Indenture, and unless the context otherwise requires, all references to the Notes shall include the Initial Notes and any Additional Notes.

 

29


Notes Parties” means, collectively, the Trustee, the Agents, each other agent, and the Holders, in each case, under this Indenture and the Collateral Agent under the Collateral Agency Agreement.

Offering Memorandum” means the Issuer’s final offering memorandum dated July 22, 2024 relating to the sale of the Initial Notes.

Officer” means, with respect to any Person, the Chairman of the Board of Directors, the Chief Executive Officer, the President, the Chief Operating Officer, the Chief Financial Officer, the Treasurer, any Assistant Treasurer, the Controller, the Secretary or any Vice-President of such Person.

Officer’s Certificate” means a certificate which meets the requirements set forth in Section 13.02 and Section 13.03, and which is signed by an Officer of the Issuer, a Guarantor or any successor Person to the Issuer or any Guarantor, as the case may be, and delivered to the Trustee.

Opinion of Counsel” means an opinion or opinions from legal counsel which opinion is reasonably acceptable to the Trustee and meets the requirements of Section 13.02 and Section 13.03. The counsel may be an employee of, or counsel to, the Issuer, any Subsidiary of the Issuer or the Trustee.

Parent Entity” means the Issuer and any Person that is the direct or indirect parent of the Issuer and of which the Issuer is a direct or indirect Subsidiary.

Participant” means, with respect to the Depositary, Euroclear or Clearstream, a Person who has an account with the Depositary, Euroclear or Clearstream, respectively (and, with respect to DTC, shall include Euroclear and Clearstream).

Permitted Business” means (a)(i) any businesses, services or activities engaged in by the Issuer or any of its Subsidiaries on the Issue Date, (ii) any Project, and any businesses, services or activities engaged in by the Issuer or any of its Subsidiaries in connection with any Project, including in connection with preparing for, and implementing any Project, and (iii) any businesses, services and activities engaged in by the Issuer or any of its Subsidiaries that are reasonably related, complementary, incidental, synergistic, ancillary or similar to any of the foregoing or are, in whole or in part, extensions, expansions or developments of any thereof, and (b) where the context requires, any Person engaged primarily in the businesses, services or activities described in clause (a) of this definition, in each case, as determined by the Issuer in good faith.

Permitted Business Investments” means Investments by the Issuer or any of its Restricted Subsidiaries in any Person (including any Joint Venture or Unrestricted Subsidiary); provided that:

(1) such Person is engaged in a Permitted Business;

(2) except in the case of any such Investment by a Non-Recourse Subsidiary, at the time of such Investment and immediately thereafter, the Issuer could incur $1.00 of additional Indebtedness under the Holdco Debt Ratio test set forth in Section 4.09(a); and

 

30


(3) if, upon consummation of such Investment, such Person will be a Restricted Subsidiary, then if either such Restricted Subsidiary will be a Recourse Person and has outstanding any Indebtedness, or such Person will be a Non-Recourse Subsidiary and has outstanding Indebtedness at the time of such Investment that is recourse to any Recourse Person, then in each case such Person could, at the time such Investment is made, incur such Indebtedness at such time pursuant to Section 4.09.

Permitted Holder” means (a) the Investors and (b) any Person with which one or more Investors form a “group” (within the meaning of Section 14(d) of the Exchange Act as in effect on the date of this Indenture) so long as, in the case of this clause (b), such one or more Investors directly or indirectly collectively Beneficially Own more than 50% of the aggregate voting Equity Interests that are Beneficially Owned by the group.

Permitted Intercompany Activities” means any transactions between or among the Issuer and its Restricted Subsidiaries that are entered into in the ordinary course of business, consistent with past practice or industry norms, or that are reasonably necessary, appropriate or advisable in connection with the ownership or operation of the business of the Issuer and its Restricted Subsidiaries, including, but not limited to, (i) payroll, cash management, netting, overdraft protection, purchasing, insurance and hedging arrangements; (ii) management, technology and licensing arrangements; and (iii) marketing and other professional services and shipping and maintenance arrangements.

Permitted Investment” means:

(1) any Investment in the Issuer or any Restricted Subsidiary;

(2) any Investment in a Person, if as a result of such Investment:

(i) such Person becomes a Restricted Subsidiary; or

(ii) such Person is merged, consolidated or amalgamated with or into, or transfers all or substantially all of its assets to, or is liquidated into, the Issuer or a Restricted Subsidiary, and in each case, any Investment held by any such Person; provided that such Investment was not made by such Person in contemplation of such Person becoming a Restricted Subsidiary or such merger, consolidation, amalgamation, transfer or liquidation;

(3) any Investment in cash or Cash Equivalents;

(4) any Investment made as a result of the receipt of non-cash consideration from an Asset Sale that was made pursuant to and in compliance with Section 4.10 or any other disposition of assets not constituting an Asset Sale;

(5) any Investment existing on the Issue Date and any extension, modification or renewal of any such Investments (but not any such extension, modification or renewal to the extent it involves additional advances, contributions or other investments of cash or property, except as otherwise permitted under this Indenture);

 

31


(6) (a) any acquisition of assets solely in exchange for the issuance of Equity Interests (other than Disqualified Stock) of the Issuer and (b) advances and prepayments for asset purchases (i) in the ordinary course of business or (ii) if such asset purchases would otherwise constitute a Permitted Investment;

(7) (i) extensions of trade credit (or notes receivable arising from such grant) and deposits, prepayments and other credits to suppliers made in the ordinary course of business, and Investments received in compromise or resolution thereof from financially troubled account debtors or in connection with the bankruptcy or reorganization of suppliers or customers or in settlement of delinquent obligations of, or other disputes with, suppliers and customers, and other credits to suppliers in the ordinary course of business, or (ii) any Investments received in compromise or resolution of litigation, arbitration or other disputes;

(8) Hedging Obligations permitted under Section 4.09(b)(13);

(9) (i) Investments in the Notes, including repurchases of the Notes, and (ii) Investments in the Existing Notes, including repurchases of the Existing Notes;

(10) any Investment in prepaid expenses, negotiable instruments held for collection and lease, utility, workers’ compensation and performance and other similar deposits;

(11) Management Advances;

(12) Permitted Business Investments; provided, however, that if any Investment pursuant to this clause (12) is made in any Person that is not a Restricted Subsidiary of the Issuer at the date of the making of such Investment and such Person becomes a Restricted Subsidiary after such date, such Investment shall thereafter be deemed to have been made pursuant to clause (1) above and shall cease to have been made pursuant to this clause (12);

(13) (i) any guarantee of Indebtedness permitted to be incurred pursuant to Section 4.09, (ii) any guarantee of performance obligations in the ordinary course of business, and (iii) the creation of Liens on the assets of the Issuer or any Restricted Subsidiary in compliance with Section 4.12;

(14) Investments consisting of the licensing or contribution of intellectual property pursuant to joint marketing arrangements with other Persons;

(15) extensions of credit to (and guarantees to the benefit of) customers, suppliers, vendors, contractors and service providers in the ordinary course of business including, advances to customers and suppliers that are recorded as accounts receivable, prepaid expenses or deposits on the balance sheet of the Issuer and its Restricted Subsidiaries in the ordinary course of business;

 

32


(16) other Investments made since the Issue Date in any Person having an aggregate Fair Market Value that are at that time outstanding (measured, with respect to each Investment, on the date such Investment was made and without giving effect to subsequent changes in value) not to exceed the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period; provided that if any Investment pursuant to this clause (16) is made in any Person that is not a Restricted Subsidiary of the Issuer at the date of the making of such Investment and such Person becomes a Restricted Subsidiary of the Issuer after such date, such Investment shall thereafter be deemed to have been made pursuant to clause (1) above and not this clause (16);

(17) acquisitions or other Investments consisting of assets, equipment, inventory, supplies, materials and property intended for use in any Project;

(18) payroll, travel and similar advances to cover matters that are expected at the time of such advances ultimately to be treated as expenses for accounting purposes and that are made in the ordinary course of business;

(19) trade receivables and prepaid expenses, in each case arising in the ordinary course of business; provided that such receivables and prepaid expenses would be recorded as assets in accordance with GAAP;

(20) earnest money deposits may be made to the extent required in connection with acquisitions permitted under this Indenture or the acquisition or real property and related assets;

(21) Investments by the Issuer or any Restricted Subsidiary consisting of deposits, prepayment and other credits to suppliers or landlords made in the ordinary course of business;

(22) Investments in certificates of deposit, banker’s acceptances and time deposits maturing within one year from the date of acquisition thereof issued or guaranteed by or placed with, and money market deposit accounts issued or offered by, any domestic office of any commercial bank that has a combined capital and surplus and undivided profits of not less than $500.0 million;

(23) Investments pursuant to any Project Obligations, any Permitted Project Undertaking or any Permitted Transaction;

(24) [reserved];

(25) Investments the payment for which consists of Equity Interests (other than Disqualified Stock, except to the extent issued by the Issuer to one of its Restricted Subsidiaries) of the Issuer, or redemptions in whole or in part of any of the Equity Interests of the Issuer (other than Disqualified Stock, except to the extent issued by the Issuer to one of its Restricted Subsidiaries) or with the proceeds from substantially concurrent equity contributions or new Equity Interests (and in no event shall such contribution or issuance so utilized increase the amount available as Incremental Funds for Restricted Payments pursuant to Section 4.07(a) or be duplicative of any payments pursuant to Section 4.07(b)(2)) (other than Disqualified Stock, except to the extent issued by the Issuer to one of its Restricted Subsidiaries);

 

33


(26) any transaction to the extent it constitutes an Investment that is permitted by and made in accordance with Section 4.11(b) (except transactions described in clauses (2), (7), (11) and (14) of Section 4.11(b);

(27) any Investment by any Captive Insurance Subsidiary in connection with the provision of insurance to the Issuer or any of its Subsidiaries, which Investment is made in the ordinary course of business or consistent with past practice or industry norms of such Captive Insurance Subsidiary, or by reason of applicable law, rule, regulation or order, or that is required or approved by any regulatory authority having jurisdiction over such Captive Insurance Subsidiary or its business, as applicable;

(28) Investments in connection with any Permitted Intercompany Activities and, to the extent deemed reasonably necessary by the Issuer in good faith for the consummation of, any IPO Reorganization Transaction or any Tax Restructuring;

(29) guarantees of leases or other obligations that do not constitute Indebtedness, in each case, entered into in the ordinary course of business or consistent with past practice or industry norms;

(30) Investments in or relating to a Receivables Subsidiary that, in the good faith determination of Issuer are necessary or advisable to effect any Permitted Receivables Financing (including any contribution of replacement or substitute assets to such subsidiary) or any repurchase obligation in connection therewith;

(31) Investments in connection with any Permitted Receivables Financing permitted under this Indenture, the contribution, sale or other transfer of Permitted Receivables Financing Assets, cash or Cash Equivalents made in connection with a Permitted Receivables Financing permitted under this Indenture or repurchases in connection with the foregoing (including the contribution or lending of cash and Cash Equivalents to Subsidiaries to finance the purchase of receivables or related assets from the Issuer or any Restricted Subsidiary or to otherwise fund required reserves, the contribution of replacement or substitute assets to a Receivables Subsidiary and Investments of funds held in accounts permitted or required by the arrangements governing such Permitted Receivables Financing or any related Indebtedness); and

(32) Investments in Joint Ventures having an aggregate fair market value taken together with all other Investments made pursuant to this clause (32) that are at that time outstanding not to exceed the greater of (A) $500 million and (B) 15.0% of Distributable Cash for the applicable Test Period (in each case, determined on the date such Investment is made, with the fair market value of each Investment being measured at the time made and without giving effect to subsequent changes in value), plus the amount of any returns (including dividends, payments, interest, distributions, returns of principal, profits on sale, repayments, income and similar amounts) in respect of such investments; provided, however, that if any Investment pursuant to this clause (32) is made in any Person that is not a Restricted Subsidiary of the Issuer at the date of the making of such Investment and such Person becomes a Restricted Subsidiary after such date, such Investment shall thereafter be deemed to have been made pursuant to clause (1) above and shall cease to have been made pursuant to this clause (32).

 

34


For purposes of determining compliance with this definition, in the event that a proposed Investment (or a portion thereof) meets the criteria of clauses (1) through (32) above, the Issuer will be entitled to divide or classify or later divide or reclassify (based on circumstances existing on the date of such reclassification) such Investment (or a portion thereof) between such clauses (1) through (32) in any manner that otherwise complies with this definition.

Permitted Liens” means:

(1) Liens securing Indebtedness (i) under Credit Facilities incurred pursuant to Section 4.09(b)(1) or (ii) incurred pursuant to the Holdco Debt Ratio test set forth Section 4.09(a); provided, however, that no such Liens may be created upon any asset or property that is not Collateral unless the Notes (or a Guarantee, in the case of a Lien on assets or property of a Guarantor) are equally and ratably secured with, or prior to, such Indebtedness so long as such Indebtedness is so secured (except that Liens securing subordinated Indebtedness shall be expressly subordinate to any Lien securing the Notes to at least the same extent such subordinated Indebtedness is subordinate to the Notes or such Guarantee, as the case may be);

(2) Liens on property (including Capital Stock) of a Person existing at the time such Person becomes a Restricted Subsidiary or is merged with or into or consolidated with the Issuer or any of its Restricted Subsidiaries; provided that such Liens were in existence prior to the contemplation of such Person becoming a Restricted Subsidiary or such merger or consolidation, were not incurred in contemplation thereof and do not extend to any assets other than those of the Person that becomes a Restricted Subsidiary or is merged with or into or consolidated with the Issuer or any Restricted Subsidiary;

(3) Liens on property existing at the time the Issuer or any of its Restricted Subsidiaries acquires such property; provided that such Liens were in existence prior to the contemplation of such acquisition, were not incurred in contemplation thereof and do not extend to any other assets of the Issuer or any of its Restricted Subsidiary;

(4) Liens securing Indebtedness under Bank Product Obligations, cash pooling arrangements and Hedging Obligations, which obligations are permitted by Section 4.09(b)(13) and Liens securing or arising by reason of any netting or set-off arrangement entered into in the ordinary course of banking or other trading activities;

(5) (i) Liens existing on the Issue Date and (ii) any Liens securing the Existing Notes and the related guarantees thereof;

(6) Liens in favor of the Issuer or any of its Restricted Subsidiaries;

(7) Liens for Taxes, statutory Liens of landlords, banks (and rights of set-off), of carriers, warehousemen, mechanics, repairmen, workmen and materialmen, and other Liens imposed by law;

 

35


(8) Liens incurred in the ordinary course of business in connection with workers’ compensation, unemployment insurance and other types of social security, or pledges or deposits to secure the performance of tenders, statutory obligations, surety and appeal bonds, bids, leases, concessions, government contracts, trade contracts, performance and return-of-money bonds and other similar or related obligations (exclusive of obligations for the payment of borrowed money or other Indebtedness);

(9) Liens relating to current or future escrow arrangements securing Indebtedness of the Issuer or any Guarantor (including, without limitation, arrangements for the escrow of the proceeds of Indebtedness pending consummation of an acquisition);

(10) Liens on the Capital Stock or any assets or properties of, or advances or loans to, Non-Recourse Subsidiaries (i) either securing any Non-Recourse Financing or any Project Obligations of one or more Non-Recourse Subsidiaries or (ii) or permitted pursuant to the terms thereof or by a waiver of such terms;

(11) any other Liens securing Indebtedness permitted under clauses (4), (7), (17), (18), (22), (23) or (24) of Section 4.09(b); provided that (i) Liens securing obligations relating to any Indebtedness, Disqualified Stock or Preferred Stock to be incurred pursuant to Section 4.09(b)(4) extend only to the assets so purchased, leased, developed, expanded, constructed, installed, replaced, repaired, refurbished, repositioned or improved or subject to such Sale and Leaseback (plus improvements, accessions, proceeds or dividends or distributions in respect thereof, or replacements of any thereof); provided, further, that individual financings of assets provided by one lender or group of lenders may be cross-collateralized to other financings of assets by such lender or group of lenders; (ii) Liens securing obligations relating to any Indebtedness permitted to be incurred pursuant to Section 4.09(b)(24) relate only to obligations relating to Refinancing Indebtedness that is secured by Liens on all or a portion of the same assets or the same categories or types of assets as the assets (plus improvements, accessions, proceeds or dividends or distributions in respect thereof, or replacements of any thereof) that secured (or, under the written arrangements under which the original Lien arose, could secure) the Indebtedness being refinanced; and (iii) Liens securing Indebtedness permitted to be incurred pursuant to clause (y) of Section 4.09(b)(7) shall only be permitted if such Liens are limited to all or a part of the same property or assets, including Capital Stock, acquired (plus improvements, accessions, proceeds or dividends or distributions in respect thereof, or replacements or any thereof), or of a Person acquired or merged, amalgamated or consolidated with or into the Issuer or any Restricted Subsidiary, in any transaction to which such Indebtedness relates and such Indebtedness was not incurred in contemplation of such transaction;

(12) Liens granted in favor of a Governmental Authority, including any decommissioning obligations, by a Non-Recourse Subsidiary when required by such Governmental Authority in connection with the operations of such Non-Recourse Subsidiary in the ordinary course of its business;

(13) Liens on any property or assets of any Non-Recourse Subsidiary arising out of conditional sale, title retention, hire purchase, consignment or similar arrangements for the sale or purchase of goods entered into in the ordinary course of business or consistent with past practice or industry norms;

 

36


(14) any interest or title of a lessor or sublessor under any lease or sublease of real estate permitted hereunder (or with respect to any deposits or reserves posted thereunder);

(15) Liens solely on any cash earnest money deposits made by the Issuer or any of its Restricted Subsidiaries in connection with any letter of intent or purchase agreement permitted hereunder;

(16) purported Liens evidenced by the filing of precautionary UCC financing statements relating solely to (i) operating leases of personal property entered into in the ordinary course of business, (ii) the sale of accounts receivable and/or (iii) the sale of Permitted Receivables Financing Assets and related assets in connection with any Permitted Receivables Financing;

(17) Liens in favor of customs and revenue authorities arising as a matter of law to secure payment of customs duties in connection with the importation of goods;

(18) any zoning or similar law or right reserved to or vested in any governmental office or agency to control or regulate the use of any real property;

(19) non-exclusive outbound licenses of patents, copyrights, trademarks and other intellectual property rights granted by the Issuer or any of its Restricted Subsidiaries in the ordinary course of business and not interfering in any respect with the ordinary conduct of or materially detracting from the value of the business of the Issuer or such Restricted Subsidiary;

(20) Liens given to a public authority or other service provider or any other Governmental Authority when required by such public authority or other service provider or other Governmental Authority in connection with the operations of such person in the ordinary course of business;

(21) any agreement (or provisions therein) to lease, option to lease, license, sub-lease or other right to occupancy assumed or entered by or on behalf of the Issuer or any Restricted Subsidiary in the ordinary course of its business;

(22) reservations, limitations, provisos and conditions, if any, expressed in any grants, permits, licenses or approvals from any Governmental Authority or any similar authority;

(23) Liens in the nature of restrictions on changes in the direct or indirect ownership or control of any Non-Recourse Subsidiary;

(24) Liens in the nature of rights of first refusal, rights of first offer, purchase options and similar rights in respect of the Equity Interests or assets of Non-Recourse Subsidiaries included in documentation evidencing contemplated purchase and sale transactions permitted under this Indenture, any Non-Recourse Financing or any Project Obligations;

 

37


(25) Liens securing insurance premium financing arrangements;

(26) Liens in favor of credit card companies pursuant to agreements therewith;

(27) Liens on real estate in connection with the financing of the acquisition or development thereof; provided that facilities are or will be located on such property or assets primarily for the use of the Issuer or any of its Subsidiaries;

(28) [reserved];

(29) Liens on assets pursuant to merger agreements, stock or asset purchase agreements and similar agreements in respect of the disposition of such assets;

(30) minor survey exceptions, minor encumbrances, minor defects or irregularities in title, easements or reservations of, or rights of others for, licenses, rights of way, servitudes, access rights, sewers, electric lines, open space and conservation easements, railways, water, drainage, gas and oil pipelines, light, power, internet or cable television services, telegraph and telephone lines, other utilities and other similar purposes, or zoning or other restrictions as to the use of real property, not interfering in any material respect with the conduct of the business of the Issuer and its Restricted Subsidiaries;

(31) Liens deemed to exist in connection with repurchase agreements and other similar Investments to the extent such Investments are permitted under this Indenture;

(32) Liens on the Capital Stock of any Unrestricted Subsidiary or Joint Venture to secure Indebtedness of such Unrestricted Subsidiary or Joint Venture;

(33) Liens securing Indebtedness in an aggregate principal amount not to exceed, as of the date of incurrence of such Lien or Indebtedness secured thereby, the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

(34) Liens created by or resulting from any litigation or other proceedings or resulting from operation of law with respect to any attachment, judgments, writs, awards, warrants, orders or similar Liens to the extent that such litigation, other proceedings, attachments, judgments, writs, awards, warrants or orders do not cause or constitute an Event of Default;

(35) Liens securing any security given to a public authority or other service provider or any other Governmental Authority when required by such utility or other Governmental Authority in connection with the operations of such person in the ordinary course of its business;

(36) Liens securing the Notes issued on the Issue Date (excluding, for the avoidance of doubt, Liens securing any Additional Notes) and the related Guarantees;

 

38


(37) Liens on property or assets of any Non-Recourse Subsidiary under construction (and related rights) in favor of a contractor or developer or arising from progress or partial payments by a third party relating to such property or assets;

(38) Liens on vehicles or equipment of any Non-Recourse Subsidiary in the ordinary course of business or consistent with past practice or industry norms;

(39) Liens securing Indebtedness of Recourse Persons permitted under Section 4.09; provided that such Liens are secured by Collateral and junior in priority to the Liens securing the Notes;

(40) Liens on assets securing any Indebtedness owed to any Captive Insurance Subsidiary by the Issuer or any Restricted Subsidiary;

(41) Liens securing any Project Obligations, Permitted Project Undertakings or any Permitted Transactions;

(42) Liens existing, or deemed to exist, in connection with the sale or transfer of any assets in a transaction not prohibited under this Indenture, customary rights and restrictions contained in agreements relating to such sale or transfer pending the completion thereof; and

(43) Liens (i) on accounts receivable, royalty or other revenue streams and other rights to payment and any other assets incurred in connection with a Permitted Receivables Financing, (ii) in connection with bankers’ acceptances, discounted bills of exchange or the discounting or factoring of receivables for credit management purposes, in each case incurred or undertaken in the ordinary course of business, (iii) on Permitted Receivables Financing Assets or Liens on other assets granted pursuant to Standard Securitization Undertakings, in each case, incurred in connection with Permitted Receivables Financings permitted under this Indenture and (iv) securing Refinancing Indebtedness of the foregoing.

For purposes of this definition, the term “Indebtedness” shall be deemed to include interest on such Indebtedness. In the event that a Permitted Lien meets the criteria of more than one of the types of Permitted Liens (at the time of incurrence or at a later date), the Issuer in its sole discretion may divide, classify or from time to time reclassify all or any portion of such Permitted Lien in any manner that complies with this Indenture and such Permitted Lien shall be treated as having been made pursuant only to the clause or clauses of the definition of Permitted Lien to which such Permitted Lien has been classified or reclassified.

Permitted Project Undertaking” means, as to any Person, any guarantee or other credit support provided by such Person (including any undertaking, guarantee, indemnity, agreement, letter of credit or instrument that would constitute Indebtedness), or any payment, performance or other obligation in respect of which such Person or is directly or indirectly liable (as a guaranteeing person or otherwise) or has granted a Lien on any of its assets as security (or has any obligation, contingent or otherwise, to do so), in each case, pursuant to any Project Obligation or otherwise arising in connection with any Project Document, any Project or any Permitted Business Investment (whether in favor or vendors, suppliers, contractors, customers, clients or otherwise),

 

39


in each case excluding any Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations and debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit. For the avoidance of doubt, any guarantee to be issued by any Recourse Person in favor of Baker Hughes Energy Services LLC in respect of any Purchase Order for Liquefaction Train System equipment or for Power Island System equipment in connection with any Project shall be a “Permitted Project Undertaking.”

Permitted Receivables Financing” means any securitization or other similar financing (including any factoring program) of Permitted Receivables Financing Assets that is non-recourse to the Issuer and its Restricted Subsidiaries (except for any customary limited recourse pursuant to the Standard Securitization Undertakings), and in each case, reasonable extensions thereof.

Permitted Receivables Financing Assets” means (a) any accounts receivable, loan receivables, mortgage receivables, receivables or loans relating to the financing of insurance premiums, royalty, patent or other revenue streams and other rights to payment or related assets and the proceeds thereof and (b) all assets securing or related to any such receivable or asset, all contracts and contract rights, guarantees or other obligations in respect of any such receivable or asset, lockbox accounts and records with respect to any such receivable or assets and any other assets (including inventory and proceeds thereof) customarily transferred (or in respect of which security interests are customarily granted) together with receivables or assets in connection with a securitization, factoring or receivables financing or sale transaction.

Permitted Transactions” means any of the following: (a) any Equity Financing Transaction, (b) any ECR Transaction, and (c) any prepayment, redemption, purchase, repurchase, or defeasance of all or part of any Equity Interests issued in connection with (including any Stonepeak Equity Interests), or that are the subject of, any Equity Financing Transaction or ECR Transaction.

Permitted Transferees” means, with respect to any Person that is a natural Person (and any Permitted Transferee of such Person), (a) such Person’s Immediate Family Members and (b) such Person’s estate, heirs, legatees, distributees, executors and/or administrators upon the death of such Person, or any private foundation or fund that is controlled thereby, and any other Person who was an Affiliate of such Person upon the death of such Person and who, upon such death, directly or indirectly owned Equity Interests in the Issuer or any Parent Entity.

Person” means any individual, corporation, limited liability company, partnership, joint venture, association, joint-stock company, trust, unincorporated organization or other business entity or any government or any agency or political subdivision thereof.

Pledged Equity” means, with respect to the Issuer or any Guarantor, the shares of Capital Stock of any other Person in which the Issuer or such Guarantor, as applicable, has granted a security interest to the Collateral Agent, for the benefit of the Notes Parties, pursuant to the Security Agreement, together with any other shares, stock or partnership unit certificates, options or rights of any nature whatsoever in respect of such Capital Stock that may be issued or granted to, or held by, the Issuer or such Guarantor.

 

40


Preferred Equity” or “Preferred Stock” means any Equity Interest with preferential rights of payment of dividends or upon liquidation, dissolution, or winding up.

Private Placement Legend” means the legend set forth in Section 2.06(g)(1) to be placed on all Notes issued under this Indenture, except where otherwise permitted by the provisions of this Indenture.

Project” means each of the following:

(1) any individual natural gas liquefaction and export project, together with any other businesses or assets (other than any other separate natural gas liquefaction and export project) that are reasonably related, complementary, incidental, synergistic or ancillary to such project or are, in whole or in part, extensions, expansions or developments of any thereof, as determined by the Issuer in good faith; and

(2) any one or more assets, facilities or projects in the energy industry, including natural gas pipelines, natural gas shipping assets (including liquefied natural gas carriers, tugs and floating storage units), natural gas gathering and processing projects, upstream gas projects, re-gasification projects, carbon capture and sequestration projects, in each case, together with any other businesses or assets that are reasonably related, ancillary or similar to any of the foregoing or are, in whole or in part, extensions, expansions or developments of any thereof, as determined by the Issuer in good faith.

For the avoidance of doubt, an individual “Project” for purposes of this Indenture may include any one or more of the foregoing (either alone or in combination), in each case to the extent they are reasonably related, complementary, incidental, synergistic, ancillary or similar, and any extensions, expansions or developments of any thereof (as determined by the Issuer in good faith), and still be deemed to be an individual Project for purposes of this Indenture, except that an individual Project may not include more than one individual natural gas liquefaction and export project.

Project Company” means any Restricted Subsidiary of the Issuer that (i) is the owner, lessor and/or operator of (or is formed to own, lease or operate) any Project, (ii) is the lessee, borrower, issuer or seller (or is formed to be the lessee, borrower, issuer or seller) in respect of any financing transaction entered into in connection with any Project, including any Non-Recourse Financing, Equity Financing Transaction, ECR Transaction or Sale and Leaseback Transaction, (iii) develops or constructs (or is formed to develop or construct) any Project, (iv) engages in, conducts or facilitates (or is formed to engage in, conduct or facilitate) any activities reasonably related or ancillary any activities described in clauses (i), (ii) and (iii) of this definition, and/or (v) any combination of the foregoing, in each case as determined by the Issuer in good faith.

Project Costs” means any and all costs of evaluating, acquiring, leasing, designing, engineering, procuring, purchasing, developing, constructing and operating a Project, including all costs incurred in connection with preparing for and implementing, optioning, permitting, insuring, constructing, installing, commissioning, financing (including pursuant to any Non-Recourse Financing, Equity Financing Transaction, ECR Transaction or Sale and Leaseback Transaction, and including interest, dividends and other amounts incurred or payable with respect thereto during

 

41


construction, debt service and other reserves and the cost of any associated letters of credit and other credit support or equity backstop arrangements), testing and starting-up (including costs relating to all equipment, materials, spare parts and labor), in each case, whether incurred before or after the final investment decision with respect to such Project.

Project Document” means each contract, agreement, instrument or other written undertaking entered into by a Project Company in connection with the engineering, procurement, construction, testing, commissioning, completion, insuring, operation, maintenance or repair of a Project.

Project Obligations” means as to any Person, any Contractual Obligation under any Project Document or otherwise entered into or arising in connection with any Project Document, any Project, or with respect to any Project Costs, in each case excluding any Indebtedness in respect of borrowed money, Finance Lease Obligations, purchase money obligations and debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit.

QIB” means a “qualified institutional buyer” as defined in Rule 144A.

Rating Agency” means any of the following: (a) S&P Global Ratings, a division of S&P Global Inc. (“S&P”); (b) Moody’s Investors Service, Inc. (“Moody’s”); or (c) Fitch Ratings, Inc. (“Fitch”), and, in each case, their respective successors.

Rating Decline” means, in connection with any Change of Control, the occurrence of:

(1) during the occurrence and continuance of any period in which the Notes have two or more (or, if only one of the following ratings agencies is at the applicable time providing a rating for the Notes, one) ratings equal to or greater than (x) Baa3 by Moody’s, (y) BBB- by S&P and (z) BBB- by Fitch (or, if all of such entities cease to provide such ratings, the equivalent rating from any other “nationally recognized statistical rating organization” registered with the Commission) (such period, an “Investment Grade Period”), a ratings downgrade which results in the Notes no longer having two (or, if only one of the preceding ratings agencies is at the time providing a rating for the Notes, one) such ratings of at least BBB- or Baa3, as applicable; or

(2) during any period which is not an Investment Grade Period, a ratings downgrade of the Notes by any two (or, if only one of the following ratings agencies is at the time providing a rating for such Notes, one) of (x) Moody’s, (y) S&P and (z) Fitch (or, if all of such entities cease to provide such ratings, the equivalent rating from any other “nationally recognized statistical rating organization” registered with the Commission);

provided, however, that in each case such downgrade occurs on, or within 90 days after the earlier of (a) such Change of Control, (b) the date of public notice of the occurrence of such Change of Control, or (c) public notice of the intention by the Issuer to effect such Change of Control (which period shall be extended so long as the rating of the Issuer is under publicly announced consideration for downgrade by any Rating Agency); and provided further, that a Rating Decline otherwise arising by virtue of a particular reduction in rating will not be deemed to have occurred in respect of a particular Change of Control (and thus will be disregarded in determining whether a Rating Decline has occurred for purposes of the definition of Change of Control Triggering Event) if the Rating Agencies making the reduction in rating do not announce or publicly confirm or inform the Issuer that the reduction was the result, in whole or in part, of any event or circumstance comprised of or arising as a result of, or in respect of, the applicable Change of Control (whether or not the applicable Change of Control has occurred at the time of the Rating Decline).

 

42


Receivables Subsidiary” means (i) any direct or indirect Subsidiary of any Restricted Subsidiary, whose organizational documents contain restrictions on its purpose and activities intended to preserve its separateness from such Restricted Subsidiary and/or one or more Subsidiaries of such Restricted Subsidiary, established in connection with a Permitted Receivables Financing and (ii) any Unrestricted Subsidiary involved in a Permitted Receivables Financing, which is not permitted by the terms of such Permitted Receivables Financing to guarantee the obligations under the Notes or provide Collateral.

Recourse Persons” means (a) the Issuer, (b) the Guarantors and (c) each other Restricted Subsidiary that is not a Non-Recourse Subsidiary.

Reference Date” means May 26, 2023, the date of first issuance of the Existing 2028 Notes and the Existing 2031 Notes.

Refinancing Indebtedness” means any Indebtedness that refinances any Indebtedness in compliance with Section 4.09; provided, however:

(1) such Refinancing Indebtedness has a stated maturity that is either: (i) no earlier than the stated maturity of the Indebtedness being refinanced; or (ii) after the final maturity date of the Notes then outstanding;

(2) such Refinancing Indebtedness has an average life at the time such Refinancing Indebtedness is incurred that is equal to or greater than the average life of the Indebtedness being refinanced;

(3) such Refinancing Indebtedness has an aggregate principal amount (or if issued with an original issue discount, an aggregate issue price) that is equal to or less than (i) the aggregate principal amount (or if incurred with original issue discount, the aggregate accreted value) then outstanding or committed under the Indebtedness being refinanced, plus (ii) an amount necessary to pay any fees and expenses (including original issue discount, upfront fees or similar fees) and premiums (including tender premiums) and accrued and unpaid interest, related to such modification, refinancing, refunding, extension, renewal or replacement;

(4) if the Indebtedness being refinanced is subordinated Indebtedness, such Refinancing Indebtedness has a final maturity date later than the final maturity date of the Notes then outstanding, and is subordinated in right of payment to the Notes on terms at least as favorable to the holders of Notes as those contained in the Indebtedness being refinanced; and

(5) if the Indebtedness being refinanced is a Non-Recourse Financing, such Refinancing Indebtedness is a Non-Recourse Financing incurred by one or more Non- Recourse Subsidiaries;

 

43


provided, however, that Refinancing Indebtedness shall not include Indebtedness of (i) the Issuer or a Restricted Subsidiary that refinances Indebtedness of an Unrestricted Subsidiary or a Joint Venture, (ii) the Issuer or a Guarantor that refinances Indebtedness of a Restricted Subsidiary that is not a Guarantor or (iii) a Recourse Person that refinances Indebtedness of a Non-Recourse Subsidiary.

Regulation S” means Regulation S promulgated under the Securities Act.

Regulation S Global Note” means a Regulation S Temporary Global Note or Regulation S Permanent Global Note, as appropriate.

Regulation S Permanent Global Note” means a permanent Global Note, substantially in the form of Exhibit A hereto bearing the Global Note Legend and the Private Placement Legend and deposited with or on behalf of, and registered in the name of, the Depositary or its nominee, issued in a denomination equal to the outstanding principal amount of the Regulation S Temporary Global Note upon expiration of the applicable Restricted Period.

Regulation S Temporary Global Note” means a temporary Global Note, substantially in the form of Exhibit A hereto bearing the Global Note Legend and the Private Placement Legend and the Regulation S Temporary Global Note Legend and deposited with or on behalf of, and registered in the name of, the Depositary or its nominee, issued in a denomination equal to the outstanding principal amount of the Notes initially sold in reliance on Rule 903.

Regulation S Temporary Global Note Legend” means the legend set forth in Section 2.06(g)(3) hereof.

Responsible Officer,” when used with respect to the Trustee, means any officer within the Corporate Trust Administration of the Trustee (or any successor group of the Trustee) or any other officer of the Trustee customarily performing functions similar to those performed by any of the above designated officers and also means, with respect to a particular corporate trust matter, any other officer to whom such matter is referred because of his knowledge of and familiarity with the particular subject.

Restricted Definitive Note” means a Definitive Note bearing, or that is required to bear, the Private Placement Legend.

Restricted Global Note” means a Global Note bearing, or that is required to bear, the Private Placement Legend.

Restricted Investment” means any Investment other than a Permitted Investment.

Restricted Period” means the 40-day distribution compliance period as defined in Regulation S.

Restricted Subsidiary” means any Subsidiary of the Issuer that is not an Unrestricted Subsidiary.

 

44


Retained Asset Sale Proceeds” means, at any date of determination, an amount determined on a cumulative basis of all Net Proceeds received by the Issuer or any of its Restricted Subsidiaries that, pursuant to application of the Asset Sale Prepayment Percentage, are or were not required to be applied pursuant to Section 4.10.

Rule 144” means Rule 144 promulgated under the Securities Act.

Rule 144A” means Rule 144A promulgated under the Securities Act.

Rule 144A Global Note” means a Global Note issued in accordance with Section 2.01(c).

Rule 903” means Rule 903 promulgated under the Securities Act.

Rule 904” means Rule 904 promulgated under the Securities Act.

Sale and Leaseback Transaction” means any arrangement providing for the leasing by the Issuer or any Restricted Subsidiaries of any real or tangible personal property, which property has been or is to be sold or transferred by the Issuer or such Restricted Subsidiary to a third Person in contemplation of such leasing.

Screened Affiliate” means any Affiliate of a Holder (i) that makes investment decisions independently from such Holder and any other Affiliate of such Holder that is not a Screened Affiliate, (ii) that has in place customary information screens between it and such Holder and any other Affiliate of such Holder that is not a Screened Affiliate and such screens prohibit the sharing of information with respect to the Issuer or its Subsidiaries, (iii) whose investment policies are not directed by such Holder or any other Affiliate of such Holder that is acting in concert with such Holder in connection with its investment in the Notes, and (iv) whose investment decisions are not influenced by the investment decisions of such Holder or any other Affiliate of such Holder that is acting in concert with such Holders in connection with its investment in the Notes.

Securities Act” means the Securities Act of 1933, as amended.

Security Agreement” means the Security Agreement dated as of May 26, 2023 among the Issuer, each other Grantor (as defined and referred to therein) and the Collateral Agent, as it may be amended, amended and restated, supplemented or otherwise modified from time to time.

Security Documents” means:

(1) the Security Agreement;

(2) the Collateral Agency Agreement;

(3) the Applicable Intercreditor Agreements, if any; and

(4) each of the security agreements, financing statements and other instruments executed and delivered by the Issuer or any Guarantor pursuant to this Indenture for purposes of providing collateral security or credit support for the Note Obligation; as the same may be amended, amended and restated, supplemented or otherwise modified or replaced from time to time.

 

45


Senior Class Debt Representative” means, with respect to this Indenture, the Trustee, and with respect to any Additional First Lien Debt Facility, the applicable Additional Agent that becomes a party to an Applicable Intercreditor Agreement.

Senior Indebtedness” means: (a) any Indebtedness of the Issuer that ranks equally in right of payment with the Notes; and (b) any Indebtedness of a Guarantor that ranks equally in right of payment to the Guarantee of such Guarantor.

series” means, with respect to any First Lien Obligations, each of (i) the Note Obligations, (ii) the obligations of the Issuer and guarantors, if any, with respect to the Existing 2028 Notes, the Existing 2031 Notes, the Existing May 2023 Indenture and the related guarantees, if any, and the Security Documents, (iii) the obligations of the Issuer and guarantors, if any, with respect to the Existing 2029 Notes, the Existing 2032 Notes, the Existing October 2023 Indenture and the related guarantees, if any, and the Security Documents and (iv) the Additional First Lien Obligations incurred pursuant to any Additional First Lien Debt Facility or any related Additional First Lien Documents.

Short Derivative Instruments” means, as to any person, a Derivative Instrument (i) the value of which to such person generally decreases, and/or the payment or delivery obligations of such person under which generally increase, with positive changes in the financial performance and/or position of the Issuer and/or (ii) the value of which to such person generally increases, and/or the payment or delivery obligations of such person under which generally decrease, with negative changes in the financial performance and/or position of the Issuer.

Standard Securitization Undertakings” means all representations, warranties, covenants, pledges, transfers, purchases, dispositions, guaranties and indemnities (including repurchase obligations in the event of a breach of representation and warranty) and other undertakings made or provided, and servicing obligations undertaken, by any Restricted Subsidiary or Subsidiary thereof that the Issuer has determined in good faith to be customary in connection with a Permitted Receivables Financing.

Stated Maturity” means, with respect to any installment of interest or principal on any series of Indebtedness, the date on which the payment of interest or principal was scheduled to be paid in the documentation governing such Indebtedness as of the date of this Indenture, and will not include any contingent obligations to repay, redeem or repurchase any such interest or principal prior to the date originally scheduled for the payment thereof.

Stonepeak Equity Interests” means the Equity Interests of Calcasieu Pass Holdings, LLC and Calcasieu Pass Funding, LLC owned by Stonepeak Bayou Holdings LP and Stonepeak Bayou Holdings II LP, respectively.

Subsidiary” means, with respect to any specified Person:

(1) any corporation, association or other business entity of which more than 50% of the total voting power of shares of Capital Stock entitled (without regard to the occurrence of any contingency and after giving effect to any voting agreement or stockholders’ agreement that effectively transfers voting power) to vote in the election of directors, managers or trustees of the corporation, association or other business entity is at the time owned or controlled, directly or indirectly, by that Person or one or more of the other Subsidiaries of that Person (or a combination thereof);

 

46


(2) any partnership, joint venture, limited liability company or similar entity of which: more than 50% of the capital accounts, distribution rights, total equity and voting interests or general or limited partnership interests, as applicable, are owned or controlled, directly or indirectly, by such Person or one or more of the other Subsidiaries of that Person (or a combination thereof) whether in the form of membership, general, special or limited partnership or otherwise, and such Person or any Restricted Subsidiary of such Person is a controlling general partner or otherwise controls such entity; and

(3) any other entity, the management of which is controlled, directly or indirectly (whether by way of equity ownership or contractual arrangements or otherwise), by that Person or one or more of the other Subsidiaries of that Person (or a combination thereof) and the accounts of which would be consolidated with those of the Issuer in its consolidated financial statements as of such date prepared in accordance with GAAP.

Unless otherwise specified herein, a “Subsidiary” shall refer to a Subsidiary of the Issuer.

Tax” means all present or future taxes, levies, imposts, duties, assessments, charges, fees, deductions or withholdings (together with interest, penalties and other additions thereto) of any nature and whatever called, by whomsoever, on whomsoever and wherever imposed, levied, collected, withheld or assessed.

Tax Restructuring” means any reorganizations and other activities related to tax planning and tax reorganization (as determined by the Issuer in good faith) entered into after the Issue Date so long as such Tax Restructuring does not (1) materially impair (i) the ability of the Issuer and the Guarantors to make anticipated principal or interest payments on the Notes, (ii) any Guarantees or (iii) the security interests of the Collateral Agent on behalf of holders of the Notes, in each case, taken as a whole, or (2) cause material adverse Tax consequences to the holders of the Notes.

Test Period” means, with respect to any date of determination, the most recently ended four full consecutive fiscal quarters of the Issuer for which internal financial statements are available.

Test Revenue” means, for any period, the aggregate amount of net proceeds received by the Issuer and its Restricted Subsidiaries from sales generated by assets of any Project or Permitted Business prior to such assets being placed in service for accounting purposes in accordance with GAAP, and that are recognized as an offset to construction in progress on the balance sheet of the Issuer, determined on a consolidated basis in accordance with GAAP.

TIA” means the Trust Indenture Act of 1939, as amended (15 U.S.C. §§ 77aaa-77bbbb).

 

47


Treasury Rate” means, as of any redemption date, the yield to maturity as of the earlier of (a) such redemption date or (b) the date on which the Notes are defeased or satisfied and discharged, of United States Treasury securities with a constant maturity (as compiled and published in the most recent Federal Reserve Statistical Release H.15 (519) that has become publicly available at least two Business Days prior to the redemption date (or, if such Statistical Release is no longer published, any publicly available source of similar market data)) most nearly equal to the period from the redemption date to January 15, 2027; provided, however, that if such period is less than one year, the weekly average yield on actively traded United States Treasury securities adjusted to a constant maturity of one year will be used.

Trustee” means The Bank of New York Mellon Trust Company, N.A. until a successor replaces it in accordance with the applicable provisions of this Indenture and thereafter means the successor serving hereunder.

UCC” means the Uniform Commercial Code as in effect from time to time in any applicable jurisdiction.

Unrestricted Definitive Note” means a Definitive Note that does not bear and is not required to bear the Private Placement Legend.

Unrestricted Global Note” means a Global Note that does not bear and is not required to bear the Private Placement Legend.

Unrestricted Subsidiary” means:

(1) any Subsidiary of the Issuer that at the time of determination is an Unrestricted Subsidiary (as designated by the Board of Directors of the Issuer in accordance with Section 4.17);

(2) any Subsidiary of an Unrestricted Subsidiary; and

(3) as of the Issue Date, includes VG LNG Marketing, LLC, VG LNG Marketing Pte. Ltd., CPCD, LLC, Venture Global Controls, LLC, VG Aviation, LLC, Bayou Residential, LLC, and SQRD Holding LLC.

“U.S. dollars” or “$” means the lawful currency of the United States of America.

“U.S. Person” means a U.S. Person as defined in Rule 902(k) promulgated under the Securities Act.

VG Inc.” means Venture Global, Inc.

VGP Investor” means, collectively, (a) Venture Global Partners II, LLC and its Affiliates and (b) the funds, partnerships or other co-investment vehicles managed, advised or controlled by any Person referred to in the foregoing clause (a).

Voting Stock” of any specified Person as of any date means the Capital Stock of such Person that is at that time entitled to vote in the election of the Board of Directors (or comparable governing body) of such Person, measured by voting power rather than number of shares. For the avoidance of doubt, the sole managing member of a sole-member-managed limited liability company owns 100% of the Voting Stock of such limited liability company and the sole general partner of a limited partnership owns 100% of the Voting Stock of the limited partnership.

 

48


Wholly-Owned Subsidiary” means, with respect to any specified Person, a direct or indirect Subsidiary of such Person, 100% of the outstanding Capital Stock or other ownership interests of which (other than directors’ qualifying shares) is at the time owned by such Person or by one or more Wholly-Owned Subsidiaries of such Person.

Section 1.02 Other Definitions.

 

Term

  

Defined in

Section

“Advance Offer”

   4.10(d)

“Advance Portion”

   4.10(d)

“Affiliate Transaction”

   4.11(a)

“Applicable Tax Laws”

   13.12

“Asset Sale Offer”

   4.10(d)

“Authentication Order”

   2.02

“Change of Control Offer”

   4.15(a)

“Change of Control Payment”

   4.15(b)

“Change of Control Payment Date”

   4.15(b)

“Collateral Advance Offer”

   4.10(c)

“Collateral Advance Portion”

   4.10(c)

“Collateral Asset Sale Offer”

   4.10(c)

“Collateral Excess Proceeds”

   4.10(c)

“Court Determination”

   6.02

“Covenant Defeasance”

   8.03

“Covenant Suspension Event”

   4.18(b)

“Declined Collateral Excess Proceeds”

   4.10(c)

“Declined Excess Proceeds”

   4.10(d)

“Declined Non-Collateral Excess Proceeds”

   4.10(d)

“Directing Holder”

   6.02

“DTC”

   2.03

“Event of Default”

   6.01

“Excess Proceeds”

   4.10(d)

“Guarantee Date”

   4.16

“Increased Amount”

   4.12

“Incremental Funds”

   4.07(a)

“Initial Default”

   6.02

“incur”

   4.09(a)

“Instructing Officers”

   7.02(m)

 

49


Term

  

Defined in

Section

“Instructions”

   7.02(m)

“Junior Lien Intercreditor Agreement”

   12.02(d)

“Legal Defeasance”

   8.02

“Noteholder Direction”

   6.02

“Notes Offer”

   4.10(b)(1)(A)

“Offer Amount”

   3.09(b)

“Offer Period”

   3.09(b)

“Paying Agent”

   2.03

“Permitted Debt”

   4.09(b)

“Position Representation”

   6.02

“Purchase Date”

   3.09(b)

“Registrar”

   2.03

“Restricted Payments”

   4.07

“Reversion Date”

   4.18(b)

“Subject Lien”

   4.12

“Suspended Covenants”

   4.18(b)

“Transaction Election”

   1.04

“Transaction Test Date”

   1.04

“Verification Covenant”

   6.02

Section 1.03 Rules of Construction.

(a) Unless the context otherwise requires:

(1) the table of contents and headings are for convenience only and shall not affect the interpretation of this Indenture;

(2) unless otherwise specified, references to articles, sections, clauses, appendices, exhibits, schedules or annexes are references to articles, sections, clauses, appendices, exhibits, schedules or annexes to this Indenture;

(3) references to any person, including, without limitation, any party to this Indenture or any other document or agreement, shall include its successors and permitted transferees and assigns;

(4) an “authorization” includes an authorization, consent, approval, resolution, license, exemption, filing, registration and notarization;

(5) “law” shall be construed as any law (including common or customary law), statute, constitution, decree, judgment, treaty, regulation, directive, by-law, order, ordinance or any other legislative measure of any government, supranational, local government, statutory or regulatory body or court, in each case having the force of law;

 

50


(6) unless as otherwise provided, any reference to assignment of a person’s rights and/or obligations shall be construed to refer to assignment, transfer or novation of those rights and/or obligations;

(7) any reference to the actions or omissions of agents, representatives or authorized persons shall refer only to actions or omissions taken in connection with the agency, representation or authorization;

(8) the omission of the word “any” or the phrase “if any” with respect to anything shall not imply that the thing exists or is required, notwithstanding the inclusion of such word or phrase (for clarity) in other provisions;

(9) any reference to an action being taken “pursuant to” an agreement or document, or any specified provision thereof, shall be construed to mean “pursuant to and in compliance with” the requirements of such agreement, document or provision;

(10) in some instances, a word or reference that, pursuant to these rules of interpretation, is not necessary (for example, inclusion of both the singular and plural), may be included for emphasis or clarity, and any such usage shall not give rise to any negative implication in relation to any other usage, which other usage shall nonetheless be interpreted strictly in accordance with the rules of interpretation set forth herein;

(11) a term has the meaning assigned to it;

(12) an accounting term not otherwise defined has the meaning assigned to it in accordance with GAAP;

(13) “or” is not exclusive;

(14) “including” means “including without limitation” whether or not stated;

(15) words in the singular include the plural, and in the plural include the singular;

(16) “will” shall be interpreted to express a command and shall be construed to have the same meaning and effect as the word “shall”;

(17) provisions apply to successive events and transactions;

(18) references to sections of or rules under the Securities Act will be deemed to include substitute, replacement of successor sections or rules adopted by the Commission from time to time; and

 

51


(19) references to any document, agreement or instrument means such document, agreement or instrument as it may be amended, amended and restated or otherwise modified in accordance with its terms.

Section 1.04 Limited Condition Transactions. Notwithstanding anything in this Indenture to the contrary, when (i) calculating availability under any applicable basket or ratio in this Indenture in connection with the incurrence of Indebtedness, the creation of Liens, the making of any Asset Sale, the making of any acquisitions, the making of an Investment, the making of a Restricted Payment, the designation of a Subsidiary as restricted or unrestricted, the repayment of Indebtedness or for any other purpose, (ii) determining whether any Default or Event of Default has occurred, is continuing or would result from any action, or (iii) determining compliance with any representations and warranties and any other condition precedent to any action or transaction, in each case of clauses (i) through (iii) in connection with a Limited Condition Transaction, the date of determination of such basket or ratio, whether any Default or Event of Default has occurred, is continuing or would result therefrom, or the satisfaction of any other condition precedent shall, at the option of the Issuer (the Issuer’s election to exercise such option in connection with any Limited Condition Transaction, a “Transaction Election”), be deemed to be the date of declaration of such Restricted Payment or the date that the definitive agreement for such Restricted Payment, Investment, acquisition, Asset Sale or incurrence, repayment, repurchase or refinancing of Indebtedness, Disqualified Stock or Preferred Equity is entered into, the date a public announcement of an intention to make an offer in respect of the target of such acquisition or Investment or the date of such notice, which may be conditional, of such repayment, repurchase or refinancing of Indebtedness, Disqualified Stock or Preferred Equity or such Asset Sale is given to the holders of such Indebtedness, Disqualified Stock or Preferred Equity (any such date, the “Transaction Test Date”). If on a pro forma basis after giving effect to such Limited Condition Transaction and the other transactions to be entered into in connection therewith (including any acquisitions, Investments, the incurrence or issuance of Indebtedness, Disqualified Stock or Preferred Stock and the use of proceeds thereof, the incurrence of Liens, repayments, Restricted Payments and Asset Sales) and any related pro forma adjustments, with such baskets and ratios, absence of defaults, satisfaction of conditions precedent and other provisions calculated as if such Limited Condition Transaction or other transactions had occurred on the relevant Transaction Test Date in compliance with the applicable baskets and ratios or other provisions, such provisions shall be deemed to have been complied with. For the avoidance of doubt, (i) if any of such baskets, ratios, absence of defaults, satisfaction of conditions precedent or other provisions are exceeded or breached as a result of fluctuations in such ratio (including due to fluctuations in Distributable Cash), a change in facts and circumstances or other provisions at or prior to the consummation of the relevant Limited Condition Transaction, such ratios, absence of defaults, satisfaction of conditions precedent and other provisions will not be deemed to have been exceeded, breached, or otherwise failed to have been satisfied as a result of such fluctuations or changed circumstances solely for purposes of determining whether the Limited Condition Transaction and any related transactions is permitted hereunder and (ii) such baskets and ratios and compliance with such conditions shall not be tested at the time of consummation of such Limited Condition Transaction or related transactions. If the Issuer has made a Transaction Election for any Limited Condition Transaction, then in connection with any subsequent calculation of any ratio or basket availability with respect to any other Limited Condition Transaction or otherwise on or following the relevant Transaction Test Date and prior to the earlier of the date on which such Limited Condition Transaction is consummated or the date that the definitive agreement for such Limited Condition

 

52


Transaction is terminated or expires without consummation of such Limited Condition Transaction, any such ratio or basket shall be calculated on a pro forma basis assuming such Limited Condition Transaction and other transactions in connection therewith (including any incurrence of Indebtedness and the use of proceeds thereof) have been consummated. For purposes of any calculation of any ratio that includes Fixed Charges or otherwise includes interest expense of any Indebtedness to be incurred, such Fixed Charges or interest expense may be calculated using an assumed interest rate for the Indebtedness to be incurred in connection with such Limited Condition Transaction based on the indicative interest margin contained in any financing commitment documentation with respect to such Indebtedness or, if no such indicative interest margin exists, as reasonably determined by the Issuer in good faith.

Section 1.05 Certain Compliance Calculations.

(a) Notwithstanding anything to the contrary herein, in the event an item of Indebtedness, Disqualified Stock or Preferred Equity (or any portion thereof) is incurred or issued, any Lien is incurred or other transaction is undertaken based on a ratio basket based on the Holdco Debt Ratio, such ratio(s) shall be calculated with respect to such incurrence, issuance or other transaction without giving effect to (a) amounts being utilized under any other basket (other than a ratio basket based on the Holdco Debt Ratio) on the same date, or (b) the incurrence of any Indebtedness under any revolving facility or letter of credit facility immediately prior to or in connection therewith. Each item of Indebtedness, Disqualified Stock or Preferred Equity that is incurred or issued, each Lien incurred and each other transaction undertaken will be deemed to have been incurred, issued or taken first, to the extent available, pursuant to the Holdco Debt Ratio test.

(b) For purposes of any calculation under this Indenture, the Issuer may elect, at any time (which election may not be changed with respect to such revolving Indebtedness), to either (x) give pro forma effect to the incurrence of the entire committed amount of such revolving Indebtedness, in which case such committed amount may thereafter be borrowed or reborrowed, in whole or in part, from time to time, without further compliance with any provision under this Indenture, or (y) give pro forma effect to the incurrence of the actual amount drawn under such revolving Indebtedness, in which case, the ability to incur the amounts committed to under such revolving Indebtedness will be subject to the provisions of this Indenture.

Section 1.06 Acts of Holders.

(a) Any request, demand, authorization, direction, notice, consent, waiver or other action provided by this Indenture to be given or taken by Holders may be embodied in and evidenced by one or more instruments of substantially similar tenor signed by such Holders in person or by an agent duly appointed in writing. Except as herein otherwise expressly provided, such action shall become effective when such instrument or instruments are delivered to the Trustee and, where it is hereby expressly required, to the Issuer. Proof of execution of any such instrument or of a writing appointing any such agent, or the holding by any Person of a Note, shall be sufficient for any purpose of this Indenture and (subject to Section 7.01 hereof) conclusive in favor of the Trustee and the Issuer, if made in the manner provided in this Section 1.06.

 

53


(b) The fact and date of the execution by any Person of any such instrument or writing may be proved by the affidavit of a witness of such execution or by the certificate of any notary public or other officer authorized by law to take acknowledgments of deeds, certifying that the individual signing such instrument or writing acknowledged to him the execution thereof. Where such execution is by or on behalf of any legal entity other than an individual, such certificate or affidavit shall also constitute proof of the authority of the Person executing the same. The fact and date of the execution of any such instrument or writing, or the authority of the Person executing the same, may also be proved in any other manner that the Trustee deems sufficient.

(c) Any request, demand, authorization, direction, notice, consent, waiver or other action by the Holder of any Note shall bind every future Holder of the same Note and the Holder of every Note issued upon the registration of transfer thereof or in exchange therefor or in lieu thereof, in respect of any action taken, suffered or omitted by the Trustee or the Issuer in reliance thereon, whether or not notation of such action is made upon such Note.

(d) The Issuer may set a record date for purposes of determining the identity of Holders entitled to give any request, demand, authorization, direction, notice, consent, waiver or take any other act, or to vote or consent to any action by vote or consent authorized or permitted to be given or taken by Holders. Unless otherwise specified, if not set by the Issuer prior to the first solicitation of a Holder made by any Person in respect of any such action, or in the case of any such vote, prior to such vote, any such record date shall be the later of 10 days prior to the first solicitation of such consent or the date of the most recent list of Holders furnished to the Trustee prior to such solicitation.

(e) Without limiting the foregoing, a Holder entitled to take any action hereunder with regard to any particular Note may do so with regard to all or any part of the principal amount of such Note or by one or more duly appointed agents, each of which may do so pursuant to such appointment with regard to all or any part of such principal amount. Any notice given or action taken by a Holder or its agents with regard to different parts of such principal amount pursuant to this Section 1.06(e) shall have the same effect as if given or taken by separate Holders of each such different part.

(f) Without limiting the generality of the foregoing, a Holder, including DTC and the Depositary, that is a Holder of a Global Note may make, give or take, by a proxy or proxies duly appointed in writing, any request, demand, authorization, direction, notice, consent, waiver or other action provided in this Indenture to be made, given or taken by Holders, and any Person that is a Holder of a Global Note, including DTC and the Depositary, may provide its proxy or proxies to the beneficial owners of interests in any such Global Note through such Depositary’s standing instructions and customary practices.

(g) The Issuer may fix a record date for the purpose of determining the Persons who are beneficial owners of interests in any Global Note held by DTC entitled under the procedures of such Depositary to make, give or take, by a proxy or proxies duly appointed in writing, any request, demand, authorization, direction, notice, consent, waiver or other action provided in this Indenture to be made, given or taken by Holders. If such a record date is fixed, the Holders on such record date or their duly appointed proxy or proxies, and only such Persons, shall be entitled to make, give or take such request, demand, authorization, direction, notice, consent, waiver or other action, whether or not such Holders remain Holders after such record date. No such request, demand, authorization, direction, notice, consent, waiver or other action shall be valid or effective if made, given or taken more than 120 days after such record date.

 

54


Section 1.07 Timing of Payment. Notwithstanding anything herein to the contrary, if the date on which any payment is to be made pursuant to this Indenture or the Notes is not a Business Day, the payment otherwise payable on such date shall be payable on the next succeeding Business Day with the same force and effect as if made on such scheduled date and (provided such payment is made on such succeeding Business Day) no interest shall accrue on the amount of such payment from and after such scheduled date to the time of such payment on such next succeeding Business Day and the amount of any such payment that is an interest payment will reflect accrual only through the original payment date and not through the next succeeding Business Day.

Section 1.08 Role of the Collateral Agent. The parties hereto agree that, in acting hereunder, the Collateral Agent shall be entitled to all of its rights, powers, protections and immunities set forth in the Collateral Agency Agreement (and that, in the case of any conflict between the provisions of this Indenture and the provisions of the Collateral Agency Agreement in respect of such rights, powers, protections and immunities only, the Collateral Agency Agreement shall prevail).

ARTICLE 2

THE NOTES

Section 2.01 Form and Dating.

(a) General. The Notes shall be in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The terms and provisions contained in the Notes will constitute, and are hereby expressly made, a part of this Indenture and the Issuer, the Guarantors and the Trustee, by their execution and delivery of this Indenture, expressly agree to such terms and provisions and to be bound thereby. However, to the extent any provision of any Note conflicts with the express provisions of this Indenture, the provisions of this Indenture shall govern and be controlling.

(b) Global Notes. Except as otherwise provided in this Section 2.01, Notes issued in global form (and the Trustee’s certificate of authentication of such Notes) will be substantially in the form of Exhibit A (including the Global Note Legend thereon and the “Schedule of Exchanges of Interests in the Global Note” attached thereto). Each such Note will be dated the date of its authentication. Except as otherwise provided in this Section 2.01, Notes issued in definitive form will be substantially in the form of Exhibit A (but without the Global Note Legend thereon and without the “Schedule of Exchanges of Interests in the Global Note” attached thereto). Each Global Note will represent such of the outstanding Notes as will be specified therein and each shall provide that it represents the aggregate principal amount of outstanding Notes from time to time endorsed thereon and that the aggregate principal amount of outstanding Notes represented thereby may from time to time be reduced or increased, as appropriate, to reflect exchanges and redemptions. Any endorsement of a Global Note to reflect the amount of any increase or decrease in the aggregate principal amount of outstanding Notes represented thereby will be made by the Trustee or the Custodian, at the direction of the Trustee, in accordance with instructions given by the Holder thereof as required by Section 2.06.

 

55


(c) Temporary Global Notes. Notes offered and sold in reliance on Regulation S shall be issued initially in the form of the Regulation S Temporary Global Notes duly executed by the Issuer and authenticated by the Trustee as hereinafter provided.

Following the termination of the applicable Restricted Period, the Regulation S Temporary Global Note Legend shall be deemed removed from the Regulation S Temporary Global Note for the Notes, following which temporary beneficial interests in the Regulation S Temporary Global Note shall automatically become beneficial interests in the Regulation S Permanent Global Note of the Notes pursuant to the Applicable Procedures.

The aggregate principal amount of a Regulation S Temporary Global Note for the Notes and a Regulation S Permanent Global Note of the Notes may from time to time be increased or decreased by adjustments made on the records of the Trustee and/or the Paying Agent and the Depositary or their respective nominees, as the case may be, in connection with transfers of interest as hereinafter provided.

(d) Euroclear and Clearstream Procedures Applicable. The provisions of the “Operating Procedures of the Euroclear System” and “Terms and Conditions Governing Use of Euroclear” and the “General Terms and Conditions of Clearstream Banking” and “Customer Handbook” of Clearstream will be applicable to transfers of beneficial interests in the Regulation S Temporary Global Note and the Regulation S Permanent Global Note that are held by Participants through Euroclear or Clearstream.

(e) Additional Notes. Subject to compliance with the provisions of this Indenture, the Issuer may, without notice to or the consent of the Holders from time to time after the Issue Date issue Additional Notes, ranking pari passu with the Initial Notes, and such Additional Notes shall be consolidated with and form a single class with the Initial Notes (except as otherwise provided for herein) and shall have the same terms as the Initial Notes (except for any differences in the issue price, the issue date and the interest accrued, if any); provided, however, that a separate CUSIP or ISIN will be issued for the Additional Notes, unless the Additional Notes are fungible with the Initial for U.S. federal income tax purposes. Any Additional Notes shall be issued with the benefit of an indenture supplemental to this Indenture.

Section 2.02 Execution and Authentication.

At least one Officer must sign the Notes for the Issuer by manual or electronic signature.

If an Officer whose signature is on a Note no longer holds that office at the time a Note is authenticated, the Note will nevertheless be valid.

A Note will not be valid until authenticated by the manual or electronic signature of the Trustee. The signature will be conclusive evidence that the Note has been authenticated under this Indenture.

 

56


At any time and from time to time after the execution and delivery of this Indenture, the Issuer may deliver Notes executed by the Company to the Trustee for authentication, together with a written order of the Issuer signed by at least one Officer for the authentication and delivery of such Notes (an “Authentication Order”), and the Trustee in accordance with such Authentication Order shall authenticate and deliver such Notes, without any further action by the Issuer hereunder; provided that the Trustee shall be entitled to receive an Officer’s Certificate and an Opinion of Counsel with respect to the issuance, authentication and delivery of any Additional Notes. The aggregate principal amount of Notes outstanding at any time may not exceed the aggregate principal amount of Notes authorized for issuance by the Issuer pursuant to one or more Authentication Orders, except as provided in Section 2.07.

The Trustee may appoint an authenticating agent acceptable to the Issuer to authenticate Notes. An authenticating agent may authenticate Notes whenever the Trustee may do so. Each reference in this Indenture to authentication by the Trustee includes authentication by such agent. An authenticating agent has the same rights as an Agent to deal with Holders or an Affiliate of the Issuer.

For the avoidance of any doubt, any Additional Notes that are issued in connection with a transaction in which an Officer’s Certificate and Opinion of Counsel was delivered shall be valid for all purposes and constitute Additional Notes hereunder, even if subsequently it is determined that such issuance was not in compliance with the covenants of this Indenture.

Section 2.03 Registrar and Paying Agent.

The Issuer will maintain an office or agency where Notes may be presented for registration of transfer or for exchange (“Registrar”) and an office or agency where Notes may be presented for payment (“Paying Agent”). The Registrar will keep a register of the Notes and of their transfer and exchange. The Issuer may appoint one or more co-registrars and one or more additional paying agents. The term “Registrar” includes any co-registrar and the term “Paying Agent” includes any additional paying agent. The Issuer may change any Paying Agent or Registrar without notice to any Holder. The Issuer will notify the Trustee in writing of the name and address of any Agent not a party to this Indenture. If the Issuer fails to appoint or maintain another entity as Registrar or Paying Agent, the Trustee shall act as such. The Issuer or any of its Subsidiaries may act as Paying Agent or Registrar.

The Issuer initially appoints The Depository Trust Company (“DTC”) to act as Depositary with respect to the Global Notes.

The Issuer initially appoints the Trustee to act as the Registrar and Paying Agent and to act as Custodian with respect to the Global Notes.

Section 2.04 Paying Agent to Hold Money in Trust.

The Issuer will require each Paying Agent other than the Trustee to agree in writing that the Paying Agent will hold in trust for the benefit of Holders or the Trustee all money held by the Paying Agent for the payment of principal, premium, or interest on the Notes, and will notify the Trustee of any default by the Issuer in making any such payment. While any such default continues, the Trustee may require a Paying Agent to pay all money held by it to the Trustee. The Issuer at

 

57


any time may require a Paying Agent to pay all money held by it to the Trustee. Upon payment over to the Trustee, the Paying Agent (if other than the Issuer or a Subsidiary) will have no further liability for the money. If the Issuer or a Subsidiary acts as Paying Agent, it will segregate and hold in a separate trust fund for the benefit of the Holders all money held by it as Paying Agent. Upon any bankruptcy or reorganization proceedings relating to the Issuer, the Trustee will serve as Paying Agent for the Notes.

Section 2.05 Holder Lists.

The Trustee will preserve in as current a form as is reasonably practicable the most recent list available to it of the names and addresses of all Holders. If the Trustee is not the Registrar, the Issuer on its own behalf and on behalf of the Guarantors will furnish to the Trustee at least seven Business Days before each Interest Payment Date and at such other times as the Trustee may request in writing, a list in such form and as of such date as the Trustee may reasonably require of the names and addresses of the Holders.

Section 2.06 Transfer and Exchange.

(a) Transfer and Exchange of Global Notes. A Global Note may not be transferred except as a whole by the Depositary to a nominee of the Depositary, by a nominee of the Depositary to the Depositary or to another nominee of the Depositary, or by the Depositary or any such nominee to a successor Depositary or a nominee of such successor Depositary. All Global Notes will be exchanged by the Issuer for Definitive Notes if:

(1) the Depositary notifies the Issuer that it is unwilling or unable to continue to act as Depositary for the Global Notes or that it has ceased to be a clearing agency registered under the Exchange Act and, in either case, a successor Depositary is not appointed by the Issuer within 120 days after the date of such notice from the Depositary;

(2) the Issuer, at its option, notifies the Trustee in writing that it elects to cause this issuance of Definitive Notes; provided that in no event shall the Regulation S Temporary Global Note be exchanged by the Issuer for Definitive Notes prior to (A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903(b)(3)(ii)(B) under the Securities Act; or

(3) there has occurred and is continuing an Event of Default with respect to the Notes.

Upon the occurrence of any of the preceding events, Definitive Notes shall be issued and delivered in such names as the Depositary shall instruct the Trustee, in accordance with the Depositary’s customary procedures. Global Notes also may be exchanged or replaced, in whole or in part, as provided in Section 2.07 and Section 2.10. Every Note authenticated and delivered in exchange for, or in lieu of, a Global Note or any portion thereof, pursuant to this Section 2.06 or Section 2.07 or Section 2.10, shall be authenticated and delivered in the form of, and shall be, a Global Note. A Global Note may not be exchanged for another Note other than as provided in this Section 2.06(a), however, beneficial interests in a Global Note may be transferred and exchanged as provided in Section 2.06(b) or (c).

 

58


(b) Transfer and Exchange of Beneficial Interests in the Global Notes. The transfer and exchange of beneficial interests in the Global Notes will be effected through the Depositary, in accordance with the provisions of this Indenture and the Applicable Procedures. Beneficial interests in the Restricted Global Notes will be subject to restrictions on transfer comparable to those set forth herein to the extent required by the Securities Act. Transfers of beneficial interests in the Global Notes also will require compliance with either subparagraph (1) or (2) below, as applicable, as well as one or more of the other following subparagraphs, as applicable:

(1) Transfer of Beneficial Interests in the Same Global Note. Beneficial interests in any Restricted Global Note may be transferred to Persons who take delivery thereof in the form of a beneficial interest in the same Restricted Global Note in accordance with the transfer restrictions set forth in the Private Placement Legend; provided, however, that prior to the expiration of the Restricted Period, transfers of beneficial interests in the Regulation S Temporary Global Note may not be made to a U.S. Person or for the account or benefit of a U.S. Person (other than the Initial Purchasers). Beneficial interests in any Unrestricted Global Note may be transferred to Persons who take delivery thereof in the form of a beneficial interest in an Unrestricted Global Note. No written orders or instructions shall be required to be delivered to the Registrar to effect the transfers described in this Section 2.06(b)(1).

(2) All Other Transfers and Exchanges of Beneficial Interests in Global Notes. In connection with all transfers and exchanges of beneficial interests that are not subject to Section 2.06(b)(1), the transferor of such beneficial interest must deliver to the Registrar either:

(A) both:

(i) an order from a Participant or an Indirect Participant given to the Depositary in accordance with the Applicable Procedures directing the Depositary to credit or cause to be credited a beneficial interest in another Global Note in an amount equal to the beneficial interest to be transferred or exchanged; and

(ii) instructions given in accordance with the Applicable Procedures containing information regarding the Participant account to be credited with such increase; or

(B) both:

(i) an order from a Participant or an Indirect Participant given to the Depositary in accordance with the Applicable Procedures directing the Depositary to cause to be issued a Definitive Note in an amount equal to the beneficial interest to be transferred or exchanged; and

(ii) instructions given by the Depositary to the Registrar containing information regarding the Person in whose name such Definitive Note shall be registered to effect the transfer or exchange referred to in (1) above;

 

59


provided that in no event shall Definitive Notes be issued upon the transfer or exchange of beneficial interests in the Regulation S Temporary Global Note prior to (A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903 under the Securities Act.

Upon satisfaction of all of the requirements for transfer or exchange of beneficial interests in Global Notes contained in this Indenture and the Notes or otherwise applicable under the Securities Act, the Trustee shall adjust the principal amount of the relevant Global Note(s) pursuant to Section 2.06(h).

(3) Transfer of Beneficial Interests to Another Restricted Global Note. A beneficial interest in any Restricted Global Note may be transferred to a Person who takes delivery thereof in the form of a beneficial interest in another Restricted Global Note if the transfer complies with the requirements of Section 2.06(b)(2) and the Registrar receives the following:

(A) if the transferee will take delivery in the form of a beneficial interest in the Rule 144A Global Note, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (1) thereof;

(B) if the transferee will take delivery in the form of a beneficial interest in the Regulation S Temporary Global Note or the Regulation S Permanent Global Note, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (2) thereof; and

(C) if the transferee will take delivery in the form of a beneficial interest in the IAI Global Note, then the transferor must deliver a certificate in the form of Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable.

(4) Transfer and Exchange of Beneficial Interests in a Restricted Global Note for Beneficial Interests in an Unrestricted Global Note. A beneficial interest in any Restricted Global Note may be exchanged by any Holder thereof for a beneficial interest in an Unrestricted Global Note or transferred to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note if the exchange or transfer complies with the requirements of Section 2.06(b)(2) and the Registrar receives the following:

(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a beneficial interest in an Unrestricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(a) thereof; or

(B) if the Holder of such beneficial interest in a Restricted Global Note proposes to transfer such beneficial interest to a Person who shall take delivery thereof in the form of a beneficial interest in an Unrestricted Global Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof; and, in each such case set forth in this clause (4), if the Registrar

 

60


so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Issuer to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

If any such transfer is effected pursuant to this clause (4) at a time when an Unrestricted Global Note has not yet been issued, the Issuer shall issue and, upon receipt of an Authentication Order in accordance with Section 2.02, the Trustee shall authenticate one or more Unrestricted Global Notes in an aggregate principal amount equal to the aggregate principal amount of beneficial interests transferred pursuant to this clause (4).

Beneficial interests in an Unrestricted Global Note cannot be exchanged for, or transferred to Persons who take delivery thereof in the form of, a beneficial interest in a Restricted Global Note.

(c) Transfer or Exchange of Beneficial Interests for Definitive Notes.

(1) Beneficial Interests in Restricted Global Notes to Restricted Definitive Notes. If any Holder of a beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a Restricted Definitive Note or to transfer such beneficial interest to a Person who takes delivery thereof in the form of a Restricted Definitive Note, then, upon receipt by the Registrar of the following documentation:

(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for a Restricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (2)(a) thereof;

(B) if such beneficial interest is being transferred to a QIB in accordance with Rule 144A, a certificate to the effect set forth in Exhibit B, including the certifications in item (1) thereof;

(C) if such beneficial interest is being transferred to a Non-U.S. Person in an offshore transaction in accordance with Rule 903 or Rule 904, a certificate to the effect set forth in Exhibit B, including the certifications in item (2) thereof;

(D) if such beneficial interest is being transferred pursuant to an exemption from the registration requirements of the Securities Act in accordance with Rule 144, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(a) thereof;

(E) if such beneficial interest is being transferred to an Institutional Accredited Investor in reliance on an exemption from the registration requirements of the Securities Act other than those listed in subparagraphs (B) through (D) above, a certificate to the effect set forth in Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable;

 

61


(F) if such beneficial interest is being transferred to the Issuer or any of its Subsidiaries, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(b) thereof; or

(G) if such beneficial interest is being transferred pursuant to an effective registration statement under the Securities Act, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(c) thereof,

the Trustee shall cause the aggregate principal amount of the applicable Global Note to be reduced accordingly pursuant to Section 2.06(h), and the Issuer shall execute and the Trustee shall authenticate and deliver to the Person designated in the instructions a Definitive Note in the appropriate principal amount. Any Definitive Note issued in exchange for a beneficial interest in a Restricted Global Note pursuant to this Section 2.06(c) shall be registered in such name or names and in such authorized denomination or denominations as the Holder of such beneficial interest shall instruct the Registrar through instructions from the Depositary and the Participant or Indirect Participant. The Trustee shall deliver such Definitive Notes to Holders of such Notes. Any Definitive Note issued in exchange for a beneficial interest in a Restricted Global Note pursuant to this Section 2.06(c)(1) shall bear the Private Placement Legend and shall be subject to all restrictions on transfer contained therein.

(2) Beneficial Interests in Regulation S Temporary Global Note to Definitive Notes. Notwithstanding Sections 2.06(c)(1)(A) and (C), a beneficial interest in the Regulation S Temporary Global Note may not be exchanged for a Definitive Note or transferred to a Person who takes delivery thereof in the form of a Definitive Note prior to (A) the expiration of the Restricted Period and (B) the receipt by the Registrar of any certificates required pursuant to Rule 903(b)(3)(ii)(B) under the Securities Act, except in the case of a transfer pursuant to an exemption from the registration requirements of the Securities Act other than Rule 903 or Rule 904.

(3) Beneficial Interests in Restricted Global Notes to Unrestricted Definitive Notes. A Holder of a beneficial interest in a Restricted Global Note may exchange such beneficial interest for an Unrestricted Definitive Note or may transfer such beneficial interest to a Person who takes delivery thereof in the form of an Unrestricted Definitive Note only if the Registrar receives the following:

(A) if the Holder of such beneficial interest in a Restricted Global Note proposes to exchange such beneficial interest for an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(b) thereof; or

(B) if the Holder of such beneficial interest in a Restricted Global Note proposes to transfer such beneficial interest to a Person who shall take delivery thereof in the form of an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

 

62


and, in each such case set forth in this clause (3), if the Registrar so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Issuer to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

(4) Beneficial Interests in Unrestricted Global Notes to Unrestricted Definitive Notes. If any Holder of a beneficial interest in an Unrestricted Global Note proposes to exchange such beneficial interest for a Definitive Note or to transfer such beneficial interest to a Person who takes delivery thereof in the form of a Definitive Note, then, upon satisfaction of the conditions set forth in Section 2.06(b)(2), the Trustee will cause the aggregate principal amount of the applicable Global Note to be reduced accordingly pursuant to Section 2.06(h), and the Issuer will execute and the Trustee will authenticate and deliver to the Person designated in the instructions a Definitive Note in the appropriate principal amount. Any Definitive Note issued in exchange for a beneficial interest pursuant to this Section 2.06(c)(4) will be registered in such name or names and in such authorized denomination or denominations as the Holder of such beneficial interest requests through instructions to the Registrar from or through the Depositary and the Participant or Indirect Participant. The Trustee will deliver such Definitive Notes to Holders of such Notes. Any Definitive Note issued in exchange for a beneficial interest pursuant to this Section 2.06(c)(4) will not bear the Private Placement Legend.

(d) Transfer and Exchange of Definitive Notes for Beneficial Interests.

(1) Restricted Definitive Notes to Beneficial Interests in Restricted Global Notes. If any Holder of a Restricted Definitive Note proposes to exchange such Note for a beneficial interest in a Restricted Global Note or to transfer such Restricted Definitive Notes to a Person who takes delivery thereof in the form of a beneficial interest in a Restricted Global Note, then, upon receipt by the Registrar of the following documentation:

(A) if the Holder of such Restricted Definitive Note proposes to exchange such Note for a beneficial interest in a Restricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (2)(b) thereof;

(B) if such Restricted Definitive Note is being transferred to a QIB in accordance with Rule 144A, a certificate to the effect set forth in Exhibit B, including the certifications in item (1) thereof;

(C) if such Restricted Definitive Note is being transferred to a Non-U.S. Person in an offshore transaction in accordance with Rule 903 or Rule 904, a certificate to the effect set forth in Exhibit B, including the certifications in item (2) thereof;

(D) if such Restricted Definitive Note is being transferred pursuant to an exemption from the registration requirements of the Securities Act in accordance with Rule 144, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(a) thereof;

 

63


(E) if such Restricted Definitive Note is being transferred to an Institutional Accredited Investor in reliance on an exemption from the registration requirements of the Securities Act other than those listed in subparagraphs (B) through (D) above, a certificate to the effect set forth in Exhibit B hereto, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable;

(F) if such Restricted Definitive Note is being transferred to the Issuer or any of its Subsidiaries, a certificate to the effect set forth in Exhibit B hereto, including the certifications in item (3)(b) thereof; or

(G) if such Restricted Definitive Note is being transferred pursuant to an effective registration statement under the Securities Act, a certificate to the effect set forth in Exhibit B, including the certifications in item (3)(c) thereof,

the Trustee will cancel the Restricted Definitive Note, increase or cause to be increased the aggregate principal amount of, in the case of clause (A) above, the appropriate Restricted Global Note, in the case of clause (B) above, the Rule 144A Global Note, in the case of clause (C) above, the Regulation S Global Note, in the case of clause (E) above, the IAI Global Note and in all other cases, the appropriate Unrestricted Global Note.

(2) Restricted Definitive Notes to Beneficial Interests in Unrestricted Global Notes. A Holder of a Restricted Definitive Note may exchange such Note for a beneficial interest in an Unrestricted Global Note or transfer such Restricted Definitive Note to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note only if the Registrar receives the following:

(A) if the Holder of such Definitive Notes proposes to exchange such Notes for a beneficial interest in the Unrestricted Global Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(c) thereof; or

(B) if the Holder of such Definitive Notes proposes to transfer such Notes to a Person who shall take delivery thereof in the form of a beneficial interest in the Unrestricted Global Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

and, in each such case set forth in this clause (2), if the Registrar so requests or if the Applicable Procedures so require, an Opinion of Counsel in form reasonably acceptable to the Registrar and the Issuer to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

Upon satisfaction of the conditions of any of the subparagraphs in this Section 2.06(d)(2), the Trustee will cancel the Definitive Notes and increase or cause to be increased the aggregate principal amount of the Unrestricted Global Note.

 

64


(3) Unrestricted Definitive Notes to Beneficial Interests in Unrestricted Global Notes. A Holder of an Unrestricted Definitive Note may exchange such Note for a beneficial interest in an Unrestricted Global Note or transfer such Definitive Notes to a Person who takes delivery thereof in the form of a beneficial interest in an Unrestricted Global Note at any time. Upon receipt of a request for such an exchange or transfer, the Trustee will cancel the applicable Unrestricted Definitive Note and increase or cause to be increased the aggregate principal amount of one of the Unrestricted Global Notes.

If any such exchange or transfer from a Definitive Note to a beneficial interest is effected pursuant to subparagraphs (2) or (3) above at a time when an Unrestricted Global Note has not yet been issued, the Issuer will issue and, upon receipt of an Authentication Order in accordance with Section 2.02, the Trustee will authenticate one or more Unrestricted Global Notes in an aggregate principal amount equal to the principal amount of Definitive Notes so transferred.

(e) Transfer and Exchange of Definitive Notes for Definitive Notes. Upon request by a Holder of Definitive Notes and such Holder’s compliance with the provisions of this Section 2.06(e), the Registrar will register the transfer or exchange of Definitive Notes. Prior to such registration of transfer or exchange, the requesting Holder must present or surrender to the Registrar the Definitive Notes duly endorsed or accompanied by a written instruction of transfer in form satisfactory to the Registrar duly executed by such Holder or by its attorney, duly authorized in writing. In addition, the requesting Holder must provide any additional certifications, documents and information, as applicable, required pursuant to the following provisions of this Section 2.06(e).

(1) Restricted Definitive Notes to Restricted Definitive Notes. Any Restricted Definitive Note may be transferred to and registered in the name of Persons who take delivery thereof in the form of a Restricted Definitive Note if the Registrar receives the following:

(A) if the transfer will be made pursuant to Rule 144A, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (1) thereof;

(B) if the transfer will be made pursuant to Rule 903 or Rule 904, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications in item (2) thereof; and

(C) if the transfer will be made pursuant to any other exemption from the registration requirements of the Securities Act, then the transferor must deliver a certificate in the form of Exhibit B, including the certifications, certificates and Opinion of Counsel required by item (3) thereof, if applicable.

 

65


(2) Restricted Definitive Notes to Unrestricted Definitive Notes. Any Restricted Definitive Note may be exchanged by the Holder thereof for an Unrestricted Definitive Note or transferred to a Person or Persons who take delivery thereof in the form of an Unrestricted Definitive Note if the Registrar receives the following:

(A) if the Holder of such Restricted Definitive Notes proposes to exchange such Notes for an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit C, including the certifications in item (1)(d) thereof; or

(B) if the Holder of such Restricted Definitive Notes proposes to transfer such Notes to a Person who shall take delivery thereof in the form of an Unrestricted Definitive Note, a certificate from such Holder in the form of Exhibit B, including the certifications in item (4) thereof;

and, in each such case set forth in this clause (2), if the Registrar so requests, an Opinion of Counsel in form reasonably acceptable to the Registrar to the effect that such exchange or transfer is in compliance with the Securities Act and that the restrictions on transfer contained herein and in the Private Placement Legend are no longer required in order to maintain compliance with the Securities Act.

(3) Unrestricted Definitive Notes to Unrestricted Definitive Notes. A Holder of Unrestricted Definitive Notes may transfer such Notes to a Person who takes delivery thereof in the form of an Unrestricted Definitive Note. Upon receipt of a request to register such a transfer, the Registrar shall register the Unrestricted Definitive Notes pursuant to the instructions from the Holder thereof.

(f) [Reserved].

(g) Legends. The following legends will appear on the face of all Global Notes and Definitive Notes issued under this Indenture unless specifically stated otherwise in the applicable provisions of this Indenture or any supplemental indenture governing Additional Notes.

(1) Private Placement Legend.

(A) Except as permitted by subparagraph (B) below, each Global Note and each Definitive Note (and all Notes issued in exchange therefor or substitution thereof) shall bear the legend in substantially the following form:

“THIS SECURITY HAS NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), OR THE SECURITIES LAWS OF ANY STATE OR OTHER JURISDICTION. NEITHER THIS SECURITY NOR ANY INTEREST OR PARTICIPATION HEREIN MAY BE REOFFERED, SOLD, ASSIGNED, TRANSFERRED, PLEDGED, ENCUMBERED OR OTHERWISE DISPOSED OF IN THE ABSENCE OF SUCH REGISTRATION OR UNLESS SUCH TRANSACTION IS EXEMPT FROM, OR NOT SUBJECT TO, SUCH REGISTRATION. THE HOLDER OF THIS SECURITY, BY ITS ACCEPTANCE HEREOF, AGREES ON ITS OWN BEHALF AND ON BEHALF OF ANY INVESTOR ACCOUNT FOR WHICH IT HAS PURCHASED SECURITIES, TO OFFER, SELL OR OTHERWISE TRANSFER SUCH SECURITY, ONLY (A) TO THE ISSUER, (B) PURSUANT TO A REGISTRATION STATEMENT THAT HAS BECOME OR BEEN DECLARED EFFECTIVE UNDER THE SECURITIES ACT, (C) FOR SO LONG

 

66


AS THE SECURITIES ARE ELIGIBLE FOR RESALE PURSUANT TO RULE 144A UNDER THE SECURITIES ACT, TO A PERSON IT REASONABLY BELIEVES IS A “QUALIFIED INSTITUTIONAL BUYER” AS DEFINED IN RULE 144A UNDER THE SECURITIES ACT THAT PURCHASES FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF A QUALIFIED INSTITUTIONAL BUYER TO WHOM NOTICE IS GIVEN THAT THE TRANSFER IS BEING MADE IN RELIANCE ON RULE 144A, (D) PURSUANT TO OFFERS AND SALES THAT OCCUR OUTSIDE THE UNITED STATES IN ACCORDANCE WITH REGULATION S UNDER THE SECURITIES ACT, (E) TO AN INSTITUTIONAL “ACCREDITED INVESTOR” WITHIN THE MEANING OF RULE 501(a)(1), (2), (3) OR (7) UNDER THE SECURITIES ACT THAT IS AN INSTITUTIONAL ACCREDITED INVESTOR ACQUIRING THE SECURITY FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF SUCH AN INSTITUTIONAL ACCREDITED INVESTOR, IN EACH CASE IN A MINIMUM PRINCIPAL AMOUNT OF THE SECURITIES OF $250,000, FOR INVESTMENT PURPOSES AND NOT WITH A VIEW TO OR FOR OFFER OR SALE IN CONNECTION WITH ANY DISTRIBUTION IN VIOLATION OF THE SECURITIES ACT, (F) PURSUANT TO THE EXEMPTION FROM REGISTRATION PROVIDED BY RULE 144 UNDER THE SECURITIES ACT (IF AVAILABLE) OR (G) PURSUANT TO ANOTHER AVAILABLE EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT, SUBJECT TO THE ISSUER’S AND THE TRUSTEE’S RIGHT PRIOR TO ANY SUCH OFFER, SALE OR TRANSFER PURSUANT TO CLAUSES (D), (E), (F) OR (G) TO REQUIRE THE DELIVERY OF AN OPINION OF COUNSEL, CERTIFICATION AND/OR OTHER INFORMATION SATISFACTORY TO EACH OF THEM. THIS LEGEND WILL BE REMOVED UPON THE REQUEST OF THE HOLDER AFTER THE RESALE RESTRICTION TERMINATION DATE.”

(B) Notwithstanding the foregoing, any Global Note or Definitive Note issued pursuant to subparagraphs (b)(4), (c)(3), (c)(4), (d)(2), (d)(3), (e)(2) or (e)(3) of this Section 2.06 (and all Notes issued in exchange therefor or substitution thereof) will not bear the Private Placement Legend.

(2) Global Note Legend. Each Global Note will bear a legend in substantially the following form:

“THIS GLOBAL NOTE IS HELD BY THE DEPOSITARY (AS DEFINED IN THE INDENTURE GOVERNING THIS NOTE) OR ITS NOMINEE IN CUSTODY FOR THE BENEFIT OF THE BENEFICIAL OWNERS HEREOF, AND IS NOT TRANSFERABLE TO ANY PERSON UNDER ANY CIRCUMSTANCES EXCEPT THAT (1) THE TRUSTEE MAY MAKE SUCH NOTATIONS HEREON AS MAY BE REQUIRED PURSUANT TO SECTION 2.06 OF THE INDENTURE, (2) THIS GLOBAL NOTE MAY BE EXCHANGED IN WHOLE BUT NOT IN PART PURSUANT TO SECTION 2.06(a) OF THE INDENTURE, (3) THIS GLOBAL NOTE MAY BE DELIVERED TO THE TRUSTEE FOR CANCELLATION PURSUANT TO SECTION 2.11 OF THE INDENTURE AND (4) THIS GLOBAL NOTE MAY BE TRANSFERRED TO A SUCCESSOR DEPOSITARY WITH THE PRIOR WRITTEN CONSENT OF THE ISSUER.

 

67


UNLESS AND UNTIL IT IS EXCHANGED IN WHOLE OR IN PART FOR NOTES IN DEFINITIVE FORM, THIS NOTE MAY NOT BE TRANSFERRED EXCEPT AS A WHOLE BY THE DEPOSITARY TO A NOMINEE OF THE DEPOSITARY OR BY A NOMINEE OF THE DEPOSITARY TO THE DEPOSITARY OR ANOTHER NOMINEE OF THE DEPOSITARY OR BY THE DEPOSITARY OR ANY SUCH NOMINEE TO A SUCCESSOR DEPOSITARY OR A NOMINEE OF SUCH SUCCESSOR DEPOSITARY. UNLESS THIS CERTIFICATE IS PRESENTED BY AN AUTHORIZED REPRESENTATIVE OF THE DEPOSITORY TRUST COMPANY (55 WATER STREET, NEW YORK, NEW YORK) (“DTC”), TO THE ISSUER OR ITS AGENT FOR REGISTRATION OF TRANSFER, EXCHANGE OR PAYMENT, AND ANY CERTIFICATE ISSUED IS REGISTERED IN THE NAME OF CEDE & CO. OR SUCH OTHER NAME AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC (AND ANY PAYMENT IS MADE TO CEDE & CO. OR SUCH OTHER ENTITY AS MAY BE REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC), ANY TRANSFER, PLEDGE OR OTHER USE HEREOF FOR VALUE OR OTHERWISE BY OR TO ANY PERSON IS WRONGFUL INASMUCH AS THE REGISTERED OWNER HEREOF, CEDE & CO., HAS AN INTEREST HEREIN.”

(3) Regulation S Temporary Global Note Legend. The Regulation S Temporary Global Note will bear a legend in substantially the following form:

“THIS SECURITY HAS NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), OR THE SECURITIES LAWS OF ANY STATE OR OTHER JURISDICTION, AND MAY NOT BE OFFERED, SOLD OR DELIVERED IN THE UNITED STATES OR TO, OR FOR THE ACCOUNT OR BENEFIT OF, ANY US PERSON, UNLESS SUCH NOTES ARE REGISTERED UNDER THE SECURITIES ACT OR AN EXEMPTION FROM THE REGISTRATION REQUIREMENTS THEREOF IS AVAILABLE. THIS LEGEND WILL BE REMOVED AFTER THE EXPIRATION OF FORTY DAYS FROM THE LATER OF (i) THE DATE ON WHICH THESE NOTES WAS FIRST OFFERED AND (ii) THE DATE OF ISSUE OF THESE NOTES.”

(h) Cancellation and/or Adjustment of Global Notes. At such time as all beneficial interests in a particular Global Note have been exchanged for Definitive Notes or a particular Global Note has been redeemed, repurchased or canceled in whole and not in part, each such Global Note will be returned to or retained and canceled by the Trustee in accordance with Section 2.11. At any time prior to such cancellation, if any beneficial interest in a Global Note is exchanged for or transferred to a Person who will take delivery thereof in the form of a beneficial interest in another Global Note or for Definitive Notes, the principal amount of Notes represented by such Global Note will be reduced accordingly and an endorsement will be made on such Global

 

68


Note by the Trustee or by the Depositary at the direction of the Trustee to reflect such reduction; and if the beneficial interest is being exchanged for or transferred to a Person who will take delivery thereof in the form of a beneficial interest in another Global Note, such other Global Note will be increased accordingly and an endorsement will be made on such Global Note by the Trustee or by the Depositary at the direction of the Trustee to reflect such increase.

(i) General Provisions Relating to Transfers and Exchanges.

(1) To permit registrations of transfers and exchanges, the Issuer will execute and the Trustee will authenticate Global Notes and Definitive Notes upon receipt of an Authentication Order in accordance with Section 2.02 or at the Registrar’s request.

(2) No service charge will be made to a Holder of a beneficial interest in a Global Note or to a Holder of a Definitive Note for any registration of transfer or exchange, but the Issuer may require payment of a sum sufficient to cover any transfer tax or similar governmental charge payable in connection therewith (other than any such transfer taxes or similar governmental charge payable upon exchange or transfer pursuant to Section 2.10, Section 3.06, Section 3.09, Section 4.12 and Section 4.17).

(3) The Registrar will not be required to register the transfer of or exchange of any Note selected for redemption in whole or in part, except the unredeemed portion of any Note being redeemed in part.

(4) All Global Notes and Definitive Notes issued upon any registration of transfer or exchange of Global Notes or Definitive Notes will be the valid obligations of the Issuer, evidencing the same debt, and entitled to the same benefits under this Indenture, as the Global Notes or Definitive Notes surrendered upon such registration of transfer or exchange.

(5) Neither the Registrar nor the Issuer will be required:

(A) to issue, to register the transfer of or to exchange any Notes during a period beginning at the opening of business 15 days before the day of any selection of Notes for redemption under Section 3.02 and ending at the close of business on the day of selection;

(B) to register the transfer of or to exchange any Note selected for redemption in whole or in part, except the unredeemed portion of any Note being redeemed in part; or

(C) to register the transfer of or to exchange a Note between a record date and the next succeeding Interest Payment Date.

(6) Prior to due presentment for the registration of a transfer of any Note, the Trustee, any Agent and the Issuer may deem and treat any Holder as the absolute owner of such Note for the purpose of receiving payment of principal of and interest on such Notes and for all other purposes, and none of the Trustee, any Agent or the Issuer shall be affected by notice to the contrary.

 

69


(7) The Trustee will authenticate Global Notes and Definitive Notes in accordance with the provisions of Section 2.02.

(8) All certifications, certificates and Opinions of Counsel required to be submitted to the Registrar pursuant to this Section 2.06 to effect a registration of transfer or exchange may be submitted by Electronic Means.

(9) None of the Trustee or any Agent shall have any responsibility or obligation to any beneficial owner in a Global Note, an agent member of the Depositary or other Person with respect to the accuracy of the records of the Depositary or its nominee or of any agent member of the Depositary, with respect to any ownership interest in the Notes or with respect to the delivery to any agent member of the Depositary, beneficial owner or other Person (other than the Depositary) of any notice (including any notice of redemption) or the payment of any amount, under or with respect to such Notes. All notices and communications to be given to the Holders and all payments to be made to Holders under the Notes and this Indenture shall be given or made only to or upon the order of the registered holders (which shall be the Depositary or its nominee in the case of the Global Note). The rights of beneficial owners in the Global Note shall be exercised only through the Depositary subject to the applicable procedures. The Trustee and each Agent shall be entitled to rely and shall be fully protected in relying upon information furnished by the Depositary with respect to its members, participants and any beneficial owners. The Trustee and each Agent shall be entitled to deal with the Depositary, and any nominee thereof, that is the registered holder of any Global Note for all purposes of this Indenture relating to such Global Note (including the payment of principal, premium, if any, and interest, and the giving of instructions or directions by or to the owner or holder of a beneficial ownership interest in such Global Note) as the sole holder of such Global Note and shall have no obligations to the beneficial owners thereof. None of the Trustee or any Agent shall have any responsibility or liability for any acts or omissions of the Depositary with respect to such Global Note, for the records of any such depositary, including records in respect of beneficial ownership interests in respect of any such Global Note, for any transactions between the Depositary and any agent member of the Depositary or between or among the Depositary, any such agent member of the Depositary and/or any holder or owner of a beneficial interest in such Global Note, or for any transfers of beneficial interests in any such Global Note.

(10) Notwithstanding the foregoing, with respect to any Global Note, nothing herein shall prevent the Issuer, the Trustee, any Agent, or any agent of the Issuer or the Trustee from giving effect to any written certification, proxy or other authorization furnished by any Depositary (or its nominee), as a Holder, with respect to such Global Note or shall impair, as between such Depositary and owners of beneficial interests in such Global Note, the operation of customary practices governing the exercise of the rights of such Depositary (or its nominee) as Holder of such Global Note.

 

70


None of the Trustee or any Agent shall have any obligation or duty to monitor, determine or inquire as to compliance with any restrictions on transfer imposed under this Indenture or under applicable law with respect to any transfer of any interest in any security (including any transfers between or among Depositary participants, members or beneficial owners in any Global Note) other than to require delivery of such certificates and other documentation or evidence as are expressly required by, and to do so if and when expressly required by, the terms of this Indenture, and to examine the same to determine substantial compliance as to form with the express requirements hereof.

Section 2.07 Replacement Notes.

If any mutilated Note is surrendered to the Trustee or the Issuer and the Trustee receives evidence to its satisfaction of the destruction, loss or theft of any Note, the Issuer will issue and the Trustee, upon receipt of an Authentication Order, will authenticate a replacement Note if the Trustee’s requirements are met. If required by the Trustee or the Issuer, an indemnity bond must be supplied by the Holder that is sufficient in the judgment of the Trustee and the Issuer to protect the Issuer, the Trustee, any Agent and any authenticating agent from any loss that any of them may suffer if a Note is replaced. The Issuer may charge for its expenses in replacing a Note.

Every replacement Note is an additional obligation of the Issuer and will be entitled to all of the benefits of this Indenture equally and proportionately with all other Notes duly issued hereunder.

Section 2.08 Outstanding Notes.

The Notes outstanding at any time are all the Notes authenticated by the Trustee except for those canceled by it, those delivered to it for cancellation, those reductions in the interest in a Global Note effected in accordance with the provisions hereof, and those described in this Section 2.08 as not outstanding. Except as set forth in Section 2.09, a Note does not cease to be outstanding because the Issuer or an Affiliate of the Issuer holds the Note; however, Notes held by the Issuer or an Affiliate of the Issuer shall not be deemed to be outstanding for purposes of Section 3.07.

If a Note is replaced pursuant to Section 2.07, it ceases to be outstanding unless the Trustee receives proof satisfactory to it that the replacement Note is held by a “protected purchaser” under the UCC.

If the principal amount of any Note is considered paid under Section 4.01, it ceases to be outstanding and interest on it ceases to accrue.

If the Paying Agent (other than the Issuer, a Subsidiary or an Affiliate of any thereof) holds, on a redemption date or maturity date, money sufficient to pay Notes payable on that date, then on and after that date such Notes will be deemed to be no longer outstanding and will cease to accrue interest.

Section 2.09 Treasury Notes.

In determining whether the Holders of the required principal amount of Notes have concurred in any direction, waiver or consent, Notes owned by the Issuer or any Guarantor, or by any Person directly or indirectly controlling or controlled by or under direct or indirect common control with the Issuer or any Guarantor, will be considered as though not outstanding, except that for the purposes of determining whether the Trustee will be protected in relying on any such direction, waiver or consent, only Notes that the Trustee knows are so owned will be so disregarded.

 

71


Section 2.10 Temporary Notes.

Until certificates representing Notes are ready for delivery, the Issuer may prepare and the Trustee, upon receipt of an Authentication Order, will authenticate temporary Notes. Temporary Notes will be substantially in the form of certificated Notes but may have variations that the Issuer considers appropriate for temporary Notes and as may be reasonably acceptable to the Trustee. Without unreasonable delay, the Issuer will prepare and the Trustee will authenticate definitive Notes in exchange for temporary Notes.

Holders of temporary Notes will be entitled to all of the benefits of this Indenture.

Section 2.11 Cancellation.

The Issuer at any time may deliver Notes to the Trustee for cancellation. The Registrar and Paying Agent will forward to the Trustee any Notes surrendered to them for registration of transfer, exchange or payment. The Trustee and no one else will cancel all Notes surrendered for registration of transfer, exchange, payment, replacement or cancellation and will destroy canceled Notes (subject to the record retention requirement of the Exchange Act). Certification of the destruction of all canceled Notes will be delivered to the Issuer. The Issuer may not issue new Notes to replace Notes that it has paid or that have been delivered to the Trustee for cancellation.

Section 2.12 Defaulted Interest.

If the Issuer defaults in a payment of interest on the Notes, it will pay the defaulted interest in any lawful manner plus, to the extent lawful, interest payable on the defaulted interest, to the Persons who are Holders on a subsequent special record date, in each case at the rate provided in the Notes and in Section 4.01. The Issuer will notify the Trustee in writing of the amount of defaulted interest proposed to be paid on each Note and the date of the proposed payment. The Issuer will fix or cause to be fixed each such special record date and payment date; provided that no such special record date may be less than 10 days prior to the related payment date for such defaulted interest. At least 15 days before the special record date, the Issuer (or, upon the written request of the Issuer, the Trustee in the name and at the expense of the Issuer) will deliver Holders a notice that states the special record date, the related payment date and the amount of such interest to be paid.

ARTICLE 3

REDEMPTION AND PREPAYMENT

Section 3.01 Notices to Trustee.

If the Issuer elects to redeem Notes pursuant to the optional redemption provisions of Section 3.07, it must furnish to the Trustee, at least 10 days but not more than 60 days before a redemption date, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes or a satisfaction and discharge of this Indenture pursuant to Article 8 or 12, an Officer’s Certificate setting forth:

 

  (a)

the Section of this Indenture pursuant to which the redemption shall occur;

 

72


  (b)

the redemption date;

 

  (c)

the Notes to be redeemed;

 

  (d)

the principal amount of Notes to be redeemed;

 

  (e)

the redemption price; and

 

  (f)

the CUSIP number of the Notes to be redeemed.

Section 3.02 Selection of Notes to Be Redeemed.

If less than all of the Notes are to be redeemed at any time, the Trustee will select Notes for redemption by lot or on a pro rata basis (provided that, in the case of Global Notes, Global Notes shall be selected for redemption pursuant to the Applicable Procedures) and, if applicable, with such adjustments so that only Notes in denominations of $2,000 or whole multiples of $1,000 in excess thereof will be purchased unless otherwise required by law, Applicable Procedures, or applicable stock exchange requirements.

No Notes of $2,000 or less can be redeemed in part. In the event of partial redemption, the particular Notes to be redeemed will be selected, unless otherwise provided herein, not less than 10 nor more than 60 days prior to the redemption or purchase date by the Trustee from the outstanding Notes not previously called for redemption.

The Trustee will promptly notify the Issuer in writing of the Notes selected for redemption and, in the case of any Note selected for partial redemption, the principal amount thereof to be redeemed. Notes and portions of Notes selected will be in amounts of $2,000 or whole multiples of $1,000 in excess thereof; except that if all of the Notes of a Holder are to be redeemed, the entire outstanding amount of Notes held by such Holder, even if not in the amount of $2,000 or a whole multiple of $1,000 thereof, shall be redeemed. Except as provided in the preceding sentence, provisions of this Indenture that apply to Notes called for redemption also apply to portions of Notes called for redemption.

Section 3.03 Notice of Redemption.

At least 10 days but not more than 60 days before a redemption date, the Issuer will deliver a notice of redemption to each Holder whose Notes are to be redeemed at its registered address, except that redemption notices may be delivered more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes or a satisfaction and discharge of this Indenture pursuant to Article 8 or 12.

 

73


The notice will identify the Notes to be redeemed and will state:

(a) the redemption date;

(b) the redemption price, or if not then ascertainable, the manner of calculation thereof;

(c) if any Note is being redeemed in part, the portion of the principal amount of such Note to be redeemed and that, after the redemption date upon surrender of such Note, a new Note or Notes in principal amount equal to the unredeemed portion will be issued in the name of the Holder upon cancellation of the original Note;

(d) the name and address of the Paying Agent;

(e) that Notes called for redemption must be surrendered to the Paying Agent to collect the redemption price;

(f) that, unless the Issuer defaults in making such redemption payment, interest on Notes called for redemption ceases to accrue on and after the redemption date;

(g) the paragraph of the Notes and/or Section of this Indenture pursuant to which the Notes called for redemption are being redeemed;

(h) that no representation is made as to the correctness or accuracy of the CUSIP number, if any, listed in such notice or printed on the Notes; and

(i) any conditions precedent to which the redemption is subject.

At the Issuer’s request, the Trustee will give the notice of redemption in the Issuer’s name and at its expense; provided, however, that the Issuer has delivered to the Trustee, at least 10 days prior to the redemption date (unless a shorter period is acceptable to the Trustee), an Officer’s Certificate requesting that the Trustee give such notice and setting forth the form of notice to be provided.

Any such redemption may, at the Issuer’s discretion, be subject to one or more conditions precedent, including completion of any related Equity Offerings, Change of Control or other transaction. If such redemption is subject to the satisfaction of one or more conditions precedent, the related notice of redemption shall describe each such condition, and if applicable, shall state that, in the Issuer’s discretion, the redemption date may be delayed until such time as any or all such conditions shall be satisfied or waived, or such redemption may not occur and such notice may be rescinded in the event that any or all such conditions shall not have been satisfied or waived by the redemption date, or by the redemption date as so delayed. In addition, the Issuer may provide in such notice that payment of the redemption price and performance of the Issuer’s obligations with respect to such redemption may be performed by another Person (it being understood that any such provision for payment by another Person will not relieve the Issuer and the Guarantors, if any, from their obligations with respect to such redemption in the event such other person fails to do so and all conditions to such redemption, if any, are satisfied).

 

74


Section 3.04 Effect of Notice of Redemption.

Once notice of redemption is delivered in accordance with Section 3.03, Notes called for redemption become irrevocably due and payable on the redemption date at the redemption price, subject to the fourth paragraph of Section 3.03.

Section 3.05 Deposit of Redemption Price.

Prior to 11:00 a.m. (New York City time) on the redemption date, the Issuer shall deposit with the Paying Agent money sufficient to pay the redemption price of and accrued and unpaid interest on all Notes to be redeemed on that redemption date; provided, however, that to the extent any such funds are received by the Paying Agent from the Issuer after such time on such due date, such funds will be distributed to such Persons as promptly as practicable. The Paying Agent shall promptly return to the Issuer any money deposited with such Paying Agent by the Issuer in excess of the amounts necessary to pay the redemption price of, and accrued and unpaid interest on, all Notes to be redeemed.

If the Issuer complies with the provisions of the preceding paragraph, on and after the redemption date, interest will cease to accrue on the Notes or the portions of Notes called for redemption. If a Note is redeemed on or after an interest record date but on or prior to the related Interest Payment Date, then any accrued and unpaid interest shall be paid to the Holder as at the close of business on such record date. If any Note called for redemption is not so paid upon surrender for redemption because of the failure of the Issuer to comply with the preceding paragraph, interest shall be paid on the unpaid principal, from the redemption or purchase date until such principal is paid, and to the extent lawful on any interest not paid on such unpaid principal, in each case at the rate provided in the Notes and in Section 4.01.

Section 3.06 Notes Redeemed or Purchased in Part.

Upon surrender of a Note that is redeemed in part, the Issuer will issue and, upon receipt of an Authentication Order, the Trustee will authenticate for the Holder at the expense of the Issuer a new Note equal in principal amount to the unredeemed portion of the Note surrendered.

Section 3.07 Optional Redemption.

(a) At any time prior to January 15, 2027, the Issuer may on any one or more occasions redeem up to 40% of the aggregate principal amount of the Notes issued under this Indenture prior to the redemption date, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 107.000% of the principal amount of the Notes redeemed, plus accrued and unpaid interest, if any, to the redemption date with an amount not to exceed the amount of net cash proceeds of one or more Equity Offerings consummated after the Issue Date; provided that:

(1) at least 50% of the aggregate principal amount of Notes issued under this Indenture on the Issue Date (excluding Notes held by the Issuer and its Subsidiaries) remains outstanding immediately after the occurrence of such redemption (unless all such Notes are otherwise repurchased or redeemed pursuant to another provision described under this Article 3); and

(2) the redemption occurs within 180 days of the date of the closing of such Equity Offering.

 

75


(b) At any time prior to January 15, 2027, the Issuer may on any one or more occasions redeem all or any part of the Notes upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 100% of the principal amount of the Notes redeemed, plus the Applicable Redemption Premium as of, and accrued and unpaid interest, if any, to the date of redemption.

(c) On or after January 15, 2027, the Issuer may on any one or more occasions redeem all or any part of the Notes, upon not less than 10 nor more than 60 days’ notice, at the redemption prices (expressed as a percentage of principal amount of the Notes) set forth below, plus accrued and unpaid interest, if any, to the applicable redemption date, if redeemed during the twelve-month period beginning on January 15 of the years indicated below:

 

Year

   Percentage  

2027

     103.500%  

2028

     101.750%  

2029 and thereafter

     100.000%  

Unless the Issuer defaults in the payment of the redemption price, interest will cease to accrue on the Notes or portions thereof called for redemption on the applicable redemption date.

(d) Any redemption pursuant to this Section 3.07 shall be made pursuant to the provisions of Sections 3.01 through 3.06 hereof.

(e) Notwithstanding the foregoing, in connection with any tender offer for the Notes, including a Change of Control Offer or Asset Sale Offer for the Notes, if Holders of not less than 90% in aggregate principal amount of the then outstanding Notes validly tender and do not validly withdraw such Notes in such offer and the Issuer, or any third party making such offer in lieu of the Issuer, purchase all of the Notes validly tendered and not validly withdrawn by such Holders, all of the Holders of the Notes will be deemed to have consented to such tender or other offer, and accordingly the Issuer or such third party will have the right upon not less than 10 nor more than 60 days’ prior notice, given not more than 15 days following such purchase date, to redeem all Notes that remain outstanding following such purchase at a price equal to the price offered to each other Holder (excluding any early tender or incentive fee) in such offer (which may be less than par) plus, to the extent not included in the offer payment, accrued and unpaid interest, if any, thereon, to, but excluding, the redemption date, subject to the right of Holders of record on the relevant record date to receive interest due on the relevant Interest Payment Date falling prior to or on the redemption date. In determining whether the Holders of at least 90% of the aggregate principal amount of the then outstanding Notes have validly tendered and not validly withdrawn such Notes in a tender offer, including a Change of Control Offer or Asset Sale Offer, as applicable, Notes owned by an Affiliate of the Issuer or by funds controlled or managed by any Affiliate of the Issuer, or any successor thereof, shall be deemed to be outstanding for the purposes of such tender offer, including a Change of Control Offer or Asset Sale Offer, as applicable.

 

76


Section 3.08 Mandatory Redemption; Purchases of Notes.

The Issuer will not be required to make any mandatory redemption or sinking fund payments with respect to the Notes. The Issuer, the Restricted Subsidiaries and their respective Affiliates may at any time and from time to time purchase the Notes in the open market, by tender offer, in negotiated transactions or otherwise.

Section 3.09 Offer to Purchase by Application of Excess Proceeds.

(a) In the event that, pursuant to Section 4.10 hereof, the Issuer shall be required to commence a Collateral Asset Sale Offer or an Asset Sale Offer, or if the Issuer shall elect to commence a Collateral Advance Offer or Advance Offer, the Issuer shall follow the procedures specified below.

(b) The Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall remain open for a period of 20 Business Days following its commencement and no longer, except to the extent that a longer period is required by applicable law (the “Offer Period”). No later than five Business Days after the termination of the Offer Period (the “Purchase Date”), the Issuer shall apply all Collateral Excess Proceeds or Excess Proceeds, as the case may be (the “Offer Amount”), to the purchase of Notes and, if required or permitted by the terms thereof, to other First Lien Obligations (in the case of Collateral Excess Proceeds) or to any other Senior Indebtedness (in the case of Excess Proceeds) (on a pro rata basis, if applicable, with adjustments as necessary so that no Notes or other First Lien Obligations or Senior Indebtedness, as the case may be, will be repurchased in part in an unauthorized denomination), or, if less than the Offer Amount has been tendered, all Notes and other First Lien Obligations (in the case of Collateral Excess Proceeds), or all Notes and any other Senior Indebtedness (in the case of Excess Proceeds), in each case, tendered in response to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be. Payment for any Notes so purchased shall be made in the same manner as interest payments are made.

(c) If the Purchase Date is on or after a record date and on or before the related Interest Payment Date, any accrued and unpaid interest, if any, up to but excluding the Purchase Date shall be paid to the Holder at the close of business on such record date, and no additional interest shall be payable to Holders who tender Notes pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be.

(d) Upon the commencement of a Collateral Asset Sale Offer, a Collateral Advance Offer, an Asset Sale Offer or an Advance Offer, as the case may be, the Issuer shall send, electronically or by first-class mail, a notice to each of the Holders, with a copy to the Trustee. The notice shall contain all instructions and materials necessary to enable such Holders to tender Notes pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be. The Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall be made to all Holders and, if required or permitted by the terms thereof, holders of other First Lien Obligations (in the case of Collateral Excess Proceeds) or any other Senior Indebtedness (in the case of Excess Proceeds). The notice, which shall govern the terms of the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall state:

(1) that the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, is being made pursuant to this Section 3.08 and Section 4.10 hereof and the length of time the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall remain open;

 

77


(2) the Offer Amount, the purchase price and the Purchase Date;

(3) that any Note not tendered or accepted for payment shall continue to accrue interest;

(4) that, unless the Issuer defaults in making such payment, any Note accepted for payment pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, shall cease to accrue interest on and after the Purchase Date;

(5) that any Holder electing to have less than all of the aggregate principal amount of its Notes purchased pursuant to a Collateral Asset Sale Offer, a Collateral Advance Offer, an Asset Sale Offer or an Advance Offer, as the case may be, may elect to have Notes purchased in integral multiples of $1,000;

(6) that Holders electing to have a Note purchased pursuant to any Collateral Asset Sale Offer, Collateral Advance Offer, Asset Sale Offer or Advance Offer, as the case may be, shall be required to surrender the Note, with the form entitled “Option of Holder to Elect Purchase” attached to the Note completed, or transfer such Note by book-entry transfer, to the Issuer, the applicable Depositary, if appointed by the Issuer, or a Paying Agent at the address specified in the notice at least two Business Days before the Purchase Date;

(7) that Holders shall be entitled to withdraw their election if the Issuer, the applicable Depositary or the Paying Agent, as the case may be, receives, not later than the close of business on the tenth Business Day prior to the expiration date of the Offer Period, an Electronic Means transmission or letter setting forth the name of the Holder, the principal amount of the Note the Holder delivered for purchase and a statement that such Holder is withdrawing his election to have such Note purchased;

(8) that, if the aggregate principal amount of Notes and, if applicable, other First Lien Obligations (in the case of Collateral Excess Proceeds) or any other senior Indebtedness (in the case of Excess Proceeds), in each case, surrendered by the holders thereof exceeds the Offer Amount (or, in the case of an Collateral Advance Offer or an Advance Offer, the Collateral Advance Portion or Advance Portion, respectively), the Issuer shall purchase such Notes (subject to Applicable Procedures as to Global Notes) and such other First Lien Obligations or Senior Indebtedness, as the case may be, on a pro rata basis based on the aggregate principal amount (or accreted value, if applicable) of the Notes or such other First Lien Obligations or Senior Indebtedness, as the case may be, tendered (with such adjustments as may be deemed appropriate by the Issuer so that only Notes in integral multiples of $1,000 are purchased); and

 

78


(9) that Holders whose certificated Notes were purchased only in part shall be issued new Notes equal in principal amount to the unpurchased portion of the Notes surrendered (or transferred by book-entry transfer) representing the same Indebtedness to the extent not repurchased; provided that new Notes will only be issued in denominations of $2,000 and in integral multiples of $1,000 in excess thereof.

The notice, if delivered electronically or mailed in a manner herein provided, shall be conclusively presumed to have been given, whether or not the Holder receives such notice. If (i) the notice is delivered or mailed in a manner herein provided and (ii) any Holder fails to receive such notice or a Holder receives such notice but it is defective, such Holder’s failure to receive such notice or such defect shall not affect the validity of the proceedings for the purchase of the Notes as to all other Holders that properly received such notice without defect.

(e) On or before the Purchase Date, the Issuer shall, to the extent lawful, (1) accept for payment, on a pro rata basis as described in clause (d)(8) of this Section 3.09, the Offer Amount of Notes or portions thereof validly tendered pursuant to the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, or if less than the Offer Amount has been tendered, all Notes tendered and (2) deliver or cause to be delivered to the Trustee the Notes properly accepted, together with an Officer’s Certificate stating the aggregate principal amount of Notes or portions thereof so tendered.

(f) The Issuer, the Depositary or the Paying Agent, as the case may be, shall promptly deliver to each tendering Holder an amount equal to the purchase price of the Notes properly tendered by such Holder and accepted by the Issuer for purchase, and the Issuer shall promptly issue a new Note, and the Trustee, upon receipt of an Authentication Order, shall authenticate and mail or deliver (or cause to be transferred by book-entry) such new Note to such Holder (it being understood that, notwithstanding anything in this Indenture to the contrary, only an Officer’s Certificate and not an Opinion of Counsel is required for the Trustee to authenticate and deliver such new Note) in a principal amount equal to any unpurchased portion of the Note surrendered representing the same Indebtedness to the extent not repurchased; provided, that each such new Note shall be in a principal amount of $2,000 or an integral multiple of $1,000 in excess thereof. Any Note not so accepted shall be promptly mailed or delivered by the Issuer to the Holder thereof. The Issuer shall announce the results of the Collateral Asset Sale Offer, the Collateral Advance Offer, the Asset Sale Offer or the Advance Offer, as the case may be, on or as soon as practicable after the Purchase Date on the website or online data system maintain pursuant to Section 4.03(a) hereof.

(g) Prior to 11:00 a.m. (New York City time) on the Purchase Date, the Issuer shall deposit with the Paying Agent money sufficient to pay the purchase price of and accrued and unpaid interest on all Notes to be purchased on that Purchase Date; provided, however, that to the extent any such funds are received by the Paying Agent from the Issuer after such time on such due date, such funds will be distributed to such Persons as promptly as practicable. The Paying Agent shall promptly return to the Issuer any money deposited with the Paying Agent by the Issuer in excess of the amounts necessary to pay the purchase price of, and accrued and unpaid interest on, all Notes to be redeemed.

 

79


Other than as specifically provided in this Section 3.08 or Section 4.10 hereof, any purchase pursuant to this Section 3.08 shall be made pursuant to the applicable provisions of Sections 3.01 through 3.06 hereof, and references therein to “redeem,” “redemption,” “Redemption Date” and similar words shall be deemed to refer to “purchase,” “repurchase,” “Purchase Date” and similar words, as applicable.

ARTICLE 4

COVENANTS

Section 4.01 Payment of Notes.

The Issuer will pay or cause to be paid the principal of, premium, if any, and interest, if any, on, the Notes on the dates and in the manner provided in the Notes. Principal, premium, if any, and interest, if any, will be considered paid on the date due if the Paying Agent, if other than the Issuer or a Subsidiary thereof, holds as of 11:00 a.m. (New York City time) on the due date money deposited by the Issuer in immediately available funds and designated for and sufficient to pay all principal, premium, if any, and interest, if any, then due.

Section 4.02 Maintenance of Office or Agency.

The Issuer will maintain in the Borough of Manhattan, the City of New York, an office or agency (which may be an office of the Trustee or an Affiliate of the Trustee, Registrar or co-registrar) where Notes may be surrendered for registration of transfer or for exchange and where notices and demands to or upon the Issuer in respect of the Notes and this Indenture may be served. The Issuer will give prompt written notice to the Trustee of the location, and any change in the location, of such office or agency. If at any time the Issuer fails to maintain any such required office or agency or fails to furnish the Trustee with the address thereof, such presentations, surrenders, notices and demands may be made or served at the Corporate Trust Office of the Trustee.

The Issuer may also from time to time designate one or more other offices or agencies where the Notes may be presented or surrendered for any or all such purposes and may from time to time rescind such designations; provided, however, that no such designation or rescission will in any manner relieve the Issuer of its obligation to maintain an office or agency in the Borough of Manhattan, the City of New York for such purposes. The Issuer will give prompt written notice to the Trustee of any such designation or rescission and of any change in the location of any such other office or agency.

The Issuer hereby designates the Corporate Trust Office of the Trustee as one such office or agency of the Issuer in accordance with Section 2.03.

 

80


Section 4.03

Reports.

The Issuer will deliver to the Trustee and make available to the Holders of the Notes, without cost to the Trustee or any Holder:

(a) within 120 days after the end of each fiscal year of the Issuer, an annual report containing, to the extent applicable, the following information:

(1) audited consolidated balance sheets of the Issuer and audited consolidated income statements and audited statements of cash flow of the Issuer as of and for the two most recent fiscal years, including appropriate footnotes to such financial statements, audited by an internationally recognized firm of independent public accountants, and the report of the independent public accountants of the Issuer on such financial statements; and

(2) a “management’s discussion and analysis” of the results of operations of the Issuer and its Subsidiaries on a consolidated basis for the periods presented in a level of detail comparable to the management’s discussion and analysis of the results of operations contained in the Offering Memorandum;

(b) within 60 days after the end of the first three fiscal quarters in each fiscal year of the Issuer, a quarterly report containing, to the extent applicable, the following information:

(1) an unaudited condensed consolidated balance sheet of the Issuer as of the end of such fiscal quarter and unaudited condensed statements of income and cash flow for the most recent fiscal interim period ending on the date of the unaudited condensed balance sheet, and the comparable prior year period (or comparable prior year end, in the case of such balance sheet), together with condensed footnote disclosure; and

(2) a “management’s discussion and analysis” of the results of operations of the Issuer and its Subsidiaries on a consolidated basis for the periods presented in a level of detail comparable to the management’s discussion and analysis of the results of operations contained in the Offering Memorandum;

(c) within 10 Business Days after the occurrence of any event that would require a filing with the Commission on Form 8-K under Items 1.03, 2.01 (only with respect to acquisitions that the Issuer determines in good faith are material to holders of the Notes), 4.01, 4.02(a) and (b), 5.01 and 5.02(b) (with respect to the principal executive officer, president, principal financial officer, principal accounting officer and principal operating officer only) as in effect as of the Issue Date, a notice or report containing a brief description of such event.

All such annual and quarterly financial statements will be prepared in accordance with GAAP (with the absence of year-end adjustments in the case of quarterly financial statements). For the avoidance of doubt, no report needs to include separate financial statements for the Issuer, any Guarantor or any Subsidiary that is not a Guarantor.

Notwithstanding the foregoing, with respect to any financial statements, reports, information and other disclosures provided in clauses (a) through (c) above, such (A) such financial statements, reports, information and other disclosures shall not be required to include as an exhibit, or to include a summary of the terms of, any employment or compensatory arrangement, agreement, plan or understanding between the Issuer (or any Parent Entity or Subsidiaries of the

 

81


Issuer) and any director, manager or officer, of the Issuer (or any Parent Entity or Subsidiaries of the Issuer), (B) the Issuer shall not be required to make available any information regarding the occurrence of any of the events set forth in clause (c) above if the Issuer determines in its good faith judgment that the event that would otherwise be required to be disclosed is not material to the holders of the Notes or the business, assets, operations, financial positions or prospects of the Issuer and its Restricted Subsidiaries taken as a whole, (C) no such financial statements, reports, information or other disclosures will be required to comply with Regulation G under the Exchange Act or Item 10(e) of Regulation S-K with respect to any “non-GAAP” financial information contained therein, (D) no such report will be required to comply with Regulation S-K or Regulation S-X including, without limitation, Rules 3-05, 3-09, 3-10, 3-16, 13-01, 13-02 or Article 11 thereof, (E) no such financial statements, reports, information or other disclosures will be required to provide any information that is not otherwise similar to information currently included in the Offering Memorandum, (F) in no event will such financial statements, reports, information or other disclosures be required to include as an exhibit copies of any agreements, financial statements or other items that would be required to be filed as exhibits under the Commission rules, (G) trade secrets and other information that could, in the Issuer’s good faith judgment, cause competitive harm to the Issuer and its Subsidiaries may be excluded from any such financial statements, reports, information or other disclosures, (H) such financial statements or information will not be required to contain any “segment reporting,” (I) such financial statements and information may, at the election of the Issuer, be prepared in accordance with GAAP or IFRS, (J) the Issuer may elect to change its fiscal year end, and (K) no acquired business financial statements or pro forma financial statements shall be required to be disclosed.

If the Issuer or any Parent Entity does not file reports containing such information with the SEC, then the Issuer shall make available such financial statements, reports, information and other disclosures to any Holder, in each case by posting such information on a password-protected website or online data system which shall require a confidentiality acknowledgment, and will make such information readily available to any bona fide prospective investor who agrees to treat such information as confidential; provided that the Issuer shall post such financial statements, reports, information and other disclosures thereon and make readily available any password or other login information to any such bona fide prospective investor; provided, however, that the Issuer may deny access to any competitively-sensitive information otherwise to be provided pursuant to this Section 4.03 to any such Holder or bona fide prospective investor to the extent that the Issuer determines in good faith that the provision of such information to such Person would be competitively harmful to the Issuer and its Subsidiaries; and provided, further, that such Holders and bona fide prospective investors shall agree to (A) treat all such financial statements, reports, information and other disclosures as confidential, (B) not to use such financial statements, reports, information and other disclosures for any purpose other than their investment or potential investment in the Notes and (C) not publicly disclose any such financial statements, reports, information and other disclosures.

To the extent not satisfied by this Section 4.03, the Issuer shall furnish to holders of Notes and prospective investors, upon their request, any information required to be delivered pursuant to Rule 144A(d)(4) under the Securities Act so long as the Notes are not freely transferable under the Securities Act by persons who are not “affiliates” as defined under the Securities Act.

 

82


Notwithstanding the foregoing, the Issuer may satisfy its obligations in this Section 4.03 with respect to financial information relating to the Issuer by furnishing financial information relating to any Parent Entity; provided that, if such financial information relates to any such Parent Entity that is not a Guarantor, then the same is accompanied by selected financial metrics that show the differences (in the Issuer’s sole discretion) between the information relating to such Parent Entity, on the one hand, and the information relating to the Issuer and its Subsidiaries on a standalone basis, on the other hand.

The Issuer shall use its commercially reasonable efforts to participate in quarterly conference calls (which may be a single conference call together with investors and lenders holding other securities or Indebtedness of the Issuer, its Restricted Subsidiaries and/or any direct or indirect parent of the Issuer) to discuss results of operations. The conference call will be following the last day of each fiscal quarter of the Issuer within a reasonable period of time following the time that the Issuer distributes the financial information as set forth in clauses (a) and (b) above. Prior to the conference call, the Issuer will issue a press release or otherwise announce (including, for the avoidance of doubt, by posting an announcement to a password-protected website or online data system through which information described in this Section 4.03 is provided) the time and date of such conference call and provide instructions for holders of Notes, prospective investors in the Notes, securities analysts and market making financial institutions to obtain access to such call.

To the extent any information is not provided within the time periods specified in this Section 4.03 and such information is subsequently provided, the Issuer will be deemed to have satisfied its obligations with respect thereto at such time and any Default with respect thereto shall be deemed to have been cured.

The Trustee shall not be obligated or under any duty to monitor or confirm, on a continuing basis or otherwise, the Issuer’s compliance with the covenants or with respect to any reports or other documents posted to Intralinks or another password protected website or data system or filed with the Commission or EDGAR or any website, or to participate in any conference calls.

The delivery of such reports, information and documents to the Trustee is for informational purposes only and the Trustee’s receipt of such shall not constitute actual or constructive notice or knowledge of any information contained therein or determinable from information contained therein, including the Issuer’s compliance with any of its covenants in this Indenture (as to which the Trustee is entitled to rely exclusively on Officer’s Certificates).

Section 4.04 Compliance Certificate.

(a) The Issuer shall deliver to the Trustee, within 120 days after the end of each fiscal year of the Issuer and, if timely, accompanying the annual financial statements as described in Section 4.03 of this Indenture, a statement regarding compliance with this Indenture in an Officer’s Certificate also confirming that, to the signing officer’s knowledge, no Event of Default or Default has occurred and is continuing which has not been waived, or, if the same has occurred, a description of any measures taken or proposed to be taken by the Issuer to address the same.

 

83


(b) So long as any of the Notes are outstanding, the Issuer will deliver to the Trustee, within 20 Business Days of any of their Officers becoming aware of any Default or Event of Default, an Officer’s Certificate specifying such Default or Event of Default and what action the Issuer is taking or propose to take with respect thereto, but only to the extent such Default or Event of Default has not been cured by the end of such 20 Business Day period.

Section 4.05 Taxes.

Each of the Issuer and its respective Restricted Subsidiaries (or, for the purposes of this Section 4.05, if such entity is a disregarded entity for U.S. federal income tax purposes, its owner for U.S. federal income tax purposes) will pay or cause to be paid all material Taxes (if any) imposed on it or its property by any Governmental Authority, when due, giving effect to any applicable extensions, unless these are being contested in good faith and by appropriate proceedings and an appropriate reserve has been established in respect thereof in accordance with GAAP.

Section 4.06 Stay, Extension and Usury Laws.

The Issuer and each of the Guarantors covenants (to the extent that it may lawfully do so) that it will not at any time insist upon, plead, or in any manner whatsoever claim or take the benefit or advantage of, any stay, extension or usury law wherever enacted, now or at any time hereafter in force, that may affect the covenants or the performance of this Indenture; and the Issuer and each of the Guarantors (to the extent that it may lawfully do so) hereby expressly waives all benefit or advantage of any such law, and covenants that it will not, by resort to any such law, hinder, delay or impede the execution of any power herein granted to the Trustee, but will suffer and permit the execution of every such power as though no such law has been enacted.

Section 4.07 Limitation on Restricted Payments.

(a) The Issuer will not, and will not permit any of its Restricted Subsidiaries to, directly or indirectly:

(1) declare or pay any dividend or make any other payment or distribution on account of the Issuer’s or any of its Restricted Subsidiaries’ Equity Interests (including, without limitation, any payment in connection with any merger or consolidation involving the Issuer or its Restricted Subsidiaries) or to the direct or indirect holders of the Issuer’s or any of its Restricted Subsidiaries’ Equity Interests in their capacity as holders (other than dividends or distributions payable in Equity Interests (other than Disqualified Stock) of the Issuer or any of its Restricted Subsidiaries and other than dividends or distributions payable to the Issuer or its Restricted Subsidiaries on at least a pro rata basis);

(2) purchase, redeem or otherwise acquire or retire for value (including, without limitation, in connection with any merger or consolidation involving the Issuer) any Equity Interests of the Issuer or any Parent Entity other than Equity Interests held by the Issuer or any of its Restricted Subsidiaries;

(3) make any principal payment on, or purchase, repurchase, redeem, defease or otherwise acquire or retire for value, prior to scheduled maturity, scheduled repayment or scheduled sinking fund payment, any subordinated Indebtedness (excluding any intercompany Indebtedness between or among the Issuer and any of its Restricted

 

84


Subsidiaries), except (i) a payment of principal at the Stated Maturity thereof or (ii) the purchase, repurchase, redemption, defeasance or other acquisition or retirement for value of any subordinated Indebtedness in anticipation of satisfying a sinking fund obligation, principal installment or payment at final maturity, in each case due within one year of the date of purchase, repurchase, redemption, defeasance or other acquisition or retirement for value; or

(4) make any Restricted Investment in any Person,

(all such payments and other actions set forth in clauses (1) through (4) above being collectively referred to as “Restricted Payments”), unless, at the time of any such Restricted Payment, no Event of Default has occurred and is continuing or would occur as a consequence of such Restricted Payment, and:

(A) if the Fixed Charge Coverage Ratio for the applicable Test Period at the time of such Restricted Payment is greater than or equal to 1.75 to 1.00, such Restricted Payment, together with the aggregate amount of all other Restricted Payments made by the Issuer and its Restricted Subsidiaries since the Reference Date (excluding Restricted Payments permitted by clauses (2) through (23) of Section 4.07(b)), is less than the sum, without duplication, of:

(i) Cumulative Distributable Cash, determined as of the date such Restricted Payment is made; plus

(ii) 100% of the aggregate net cash proceeds and the Fair Market Value of marketable securities and other property received by the Issuer since the Reference Date (x) as a contribution to its common equity capital or (y) in consideration of the sale or issuance of Equity Interests of the Issuer (other than Disqualified Stock or Designated Preferred Stock) or from the issue or sale of convertible or exchangeable Disqualified Stock of the Issuer or convertible or exchangeable Indebtedness of the Issuer, in each case that have been converted into or exchanged for Equity Interests of the Issuer or any Parent Entity (other than Equity Interests (or Disqualified Stock or convertible or exchangeable Indebtedness) sold to a Subsidiary of the Issuer); plus

(iii) the aggregate amount of Retained Asset Sale Proceeds and Declined Excess Proceeds since the Reference Date; plus

(iv) to the extent that any Restricted Investment that was made after the Reference Date is sold for cash or otherwise liquidated or repaid for cash, 100% of the aggregate amount received by the Issuer or its Restricted Subsidiaries in cash and the Fair Market Value of property other than cash received; plus

(v) the net reduction in Restricted Investments after the Reference Date resulting from dividends, liquidating distributions, redemptions, repayments of loans or advances, or other transfers of assets in each case to the Issuer or any of its Restricted Subsidiaries from any Person (including, without limitation, Unrestricted Subsidiaries and Joint Ventures) or from redesignation of Unrestricted Subsidiaries as Restricted Subsidiaries; plus

 

85


(vi) $2.0 billion,

in the case of each of the foregoing items (ii) through (v) for purposes of this clause (A), to the extent such amounts have not been included in Cumulative Distributable Cash for any period commencing on or after the Reference Date (such items (ii) through (v) being referred to collectively as “Incremental Funds); minus

(vii) the aggregate amount of Incremental Funds previously expended pursuant to this clause (A) or clause (B) below; or

(B) if the Fixed Charge Coverage Ratio for the applicable Test Period at the time of such Restricted Payment is less than 1.75 to 1.00, such Restricted Payment, together with the aggregate amount of all other Restricted Payments made by the Issuer and its Restricted Subsidiaries during the quarter in which such Restricted Payment is made (excluding Restricted Payments permitted by clauses (2) through (19) of Section 4.07(b)) is less than the sum, without duplication, of:

(i) the greater of (x) $2.0 billion and (y) 60.0% of Distributable Cash for the applicable Test Period, less the aggregate amount of all Restricted Payments made by the Issuer and its Restricted Subsidiaries pursuant to this clause (B)(i) during the period beginning on the Reference Date and ending on the last day of the fiscal quarter immediately preceding the quarter in which such Restricted Payment is made; plus

(ii) Incremental Funds to the extent such amounts have not previously been expended pursuant to this clause (B) or clause (A) above (including any amounts that were included in Cumulative Distributable Cash for any period commencing on or after the Reference Date and expended pursuant to clause (A) above).

(b) The preceding provisions will not prohibit:

(1) the payment of any dividend or the consummation of any redemption within 60 days after the date of declaration of the dividend or giving of the redemption notice, as the case may be, if at the date of declaration or notice, the dividend or redemption payment would have complied with this Indenture;

(2) the making of any Restricted Payment in exchange for, or out of or with the net cash proceeds of the substantially concurrent sale or issuance (other than to a Subsidiary of the Issuer) of, Equity Interests of the Issuer (other than Disqualified Stock), or from the substantially concurrent contribution to the common equity capital of the Issuer (other than from a Subsidiary of the Issuer); provided that the amount of any net cash proceeds that are utilized for any such Restricted Payment will not be or not have been included in Incremental Funds;

 

86


(3) the repurchase, redemption or other acquisition or retirement for value of any Equity Interests of the Issuer held by any future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or any of its Restricted Subsidiaries pursuant to any equity subscription agreement, stock option agreement, restricted stock grant, shareholders’ agreement or similar agreement; provided that the aggregate price paid for all such repurchased, redeemed, acquired or retired Equity Interests may not exceed $50 million in any calendar year (with unused amounts in any calendar year being carried over to succeeding calendar years); and provided further, that such amount in any calendar year may be increased by an amount not to exceed the cash proceeds from (i) the sale of Equity Interests of the Issuer received by the Issuer or a Restricted Subsidiary during such calendar year, in each case to any future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or any of its Restricted Subsidiaries (to the extent not included in Incremental Funds) and (ii) key man life insurance policies received by the Issuer or any of its Restricted Subsidiaries in such calendar year;

(4) the defeasance, redemption, repurchase, repayment or other acquisition of subordinated Indebtedness with the net cash proceeds from an incurrence of Refinancing Indebtedness;

(5) the repurchase, redemption or other acquisition or retirement for value of any Preferred Stock, any Disqualified Stock or any subordinated Indebtedness pursuant to provisions similar to those described in Sections 4.10 and 4.15 hereof; provided that all Notes tendered by Holders of the Notes in connection with a Change of Control Offer or Asset Sale Offer, as applicable, have been repurchased, redeemed or acquired for value;

(6) [reserved];

(7) [reserved];

(8) the declaration and payment of regularly scheduled or accrued dividends to holders of any class or series of Disqualified Stock of the Issuer or its Restricted Subsidiaries or any Preferred Equity of any Restricted Subsidiary (other than the Issuer or the Guarantors) issued on or after the Reference Date in accordance with Section 4.09;

(9) payments of cash, dividends, distributions, advances or other Restricted Payments by the Issuer or any of its Restricted Subsidiaries to allow the payment of cash in lieu of the issuance of fractional shares upon the exercise of options, warrants or similar securities or the conversion or exchange of Capital Stock of any such Person;

(10) (i) the declaration and payment of dividends to holders of any class or series of Designated Preferred Stock (other than Disqualified Stock) issued by the Issuer after the Reference Date; provided that for the applicable Test Period, after giving effect to such issuance or declaration on a pro forma basis, the Issuer could incur $1.00 of additional Indebtedness pursuant to Section 4.09(a); and (ii) the declaration and payment of dividends

 

87


to any Parent Entity, the proceeds of which will be used to fund the payment of dividends to holders of any class or series of Designated Preferred Stock (other than Disqualified Stock) issued by such Parent Entity after the Reference Date; provided that the amount of dividends paid pursuant to this subclause (ii) shall not exceed the aggregate amount of cash actually contributed to the Issuer from the sale of such Designated Preferred Stock;

(11) the payment of any dividend (or, in the case of any partnership or limited liability company, any similar distribution) by a Restricted Subsidiary to the holders of its Equity Interests in accordance with the charter, partnership agreement, limited liability company agreement or other governing documents of such Restricted Subsidiary or on a pro rata basis or a more favorable basis to the Issuer or the Restricted Subsidiary that is the parent of the Restricted Subsidiary making such payment;

(12) any payments pursuant to clauses (19) through (21) of Section 4.11(b)(19);

(13) additional Restricted Payments made after the Issue Date in an aggregate amount pursuant to this clause (13) not to exceed the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period;

(14) other Restricted Payments, so long as the Holdco Debt Ratio is no greater than 0.95 to 1.0 determined on a pro forma basis for the applicable Test Period; provided, however, that at the time of, and after giving effect to, any Restricted Payment permitted under this clause (14), no Event of Default shall have occurred and be continuing or would otherwise occur as a consequence thereof;

(15) the purchase by the Issuer of fractional shares arising out of stock dividends, splits or combinations or business combinations and payments or distributions to dissenting stockholders pursuant to applicable law in connection with a consolidation, merger or transfer of assets;

(16) dividends or other distributions by the Issuer or any Restricted Subsidiary of (x) Capital Stock of an Unrestricted Subsidiary, or (y) Indebtedness owed to the Issuer or a Restricted Subsidiary by, an Unrestricted Subsidiary, in each case, other than an Unrestricted Subsidiary the principal asset of which is (i) cash and Cash Equivalents or (ii) intellectual property that is material to the Issuer and its Subsidiaries, taken as a whole;

(17) any prepayment, redemption, purchase, repurchase or defeasance of Equity Interests or subordinated Indebtedness pursuant to a Permitted Transaction;

(18) any prepayment, redemption, purchase, repurchase or defeasance of any Equity Interests (i) pursuant to any definitive agreement in effect as of the Reference Date and (ii) up to an additional aggregate amount pursuant to this clause (18) not to exceed $1.5 billion;

(19) the defeasance, redemption, repurchase, repayment or other acquisition of subordinated Indebtedness that constitutes a Non-Recourse Financing;

 

88


(20) (i) the declaration and payment of dividends on the common stock or common Equity Interests of the Issuer or any Parent Entity (and any equivalent declaration and payment of a distribution of any security exchangeable for such common stock or common Equity Interests to the extent required by the terms of any such exchangeable securities and any Restricted Payment to any such Parent Entity to fund the payment by such Parent Entity of dividends on such entity’s Capital Stock), following a public offering of such common stock or common Equity Interests (or such exchangeable securities, as applicable), in an amount in any fiscal year not to exceed the sum of (A) 7% of the amount of net cash proceeds received by or contributed to the Issuer or any of its Restricted Subsidiaries from any such public offering and (B) 7% of Market Capitalization; or (ii) in lieu of all or a portion of the dividends permitted by subclause (i), any prepayment, purchase, repurchase, redemption, defeasance, discharge, retirement or other acquisition of the Issuer’s Capital Stock (and any equivalent prepayment, purchase, repurchase, redemption, defeasance, discharge, retirement or other acquisition of any security exchangeable for such common stock or common equity interests to the extent required by the terms of any such exchangeable securities and any Restricted Payment to any Parent Entity to fund the prepayment, purchase, repurchase, redemption, defeasance, discharge, retirement or other acquisition of such entity’s Capital Stock) for aggregate consideration that, when taken together with dividends permitted by subclause (i), does not exceed the amount contemplated by subclause (i);

(21) Restricted Payments made in connection with or relating to, and deemed reasonably necessary by the Issuer in good faith for the consummation of, any IPO Reorganization Transactions or Tax Restructuring; provided that if immediately after giving pro forma effect to any such IPO Reorganization Transactions or Tax Restructuring and the transactions to be consummated in connection therewith, any distributed asset ceases to be owned by the Issuer or any Restricted Subsidiary (or any entity ceases to be a Restricted Subsidiary), the applicable portion of such Restricted Payment must be otherwise permitted under another provision of this covenant (and constitute utilization of such other Restricted Payment exception or capacity);

(22) payments made or expected to be made (including repurchases of Capital Stock) by the Issuer or any of its Restricted Subsidiaries in respect of withholding or similar Taxes payable in connection with the exercise or vesting of Capital Stock or any other equity award by any future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Issuer or any of its Restricted Subsidiaries or any Parent Entity and purchases, repurchases, redemptions, defeasances or other acquisitions or retirements of Capital Stock deemed to occur upon the exercise, conversion or exchange of stock options, warrants, equity-based awards or other rights in respect thereof if such Capital Stock represents a portion of the exercise price thereof or payments in respect of withholding or similar Taxes payable upon exercise or vesting thereof; and

(23) distributions or payments made directly or by means of discounts with respect to any participation interest issued or sold in connection with, and other fees paid to a Person that is not a Receivables Subsidiary in connection with, any Permitted Receivables Financing.

 

89


(c) The amount of all Restricted Payments (other than cash) shall be the Fair Market Value on the date of such Restricted Payment of the asset(s) or securities proposed to be paid, transferred or issued by the Issuer or such Restricted Subsidiary, as the case may be, pursuant to such Restricted Payment, without giving effect to subsequent changes in value. The Fair Market Value of any cash Restricted Payment shall be its face amount.

(d) For purposes of determining compliance with this Section 4.07, in the event that a proposed Restricted Payment (or a portion thereof) meets the criteria of clauses (1) through (23) of Section 4.07(b) or is entitled to be made pursuant to Section 4.07(a) or as a Permitted Investment, the Issuer will be able to classify or later reclassify (based on circumstances existing on the date of such reclassification) such Restricted Payment (or a portion thereof) between such clauses (1) through (23) of Section 4.07(b) and Section 4.07(a) or as a Permitted Investment in any manner that otherwise complies with this Section 4.07.

(e) For the avoidance of doubt, this Section 4.07 shall not restrict the making of any “AHYDO catch-up payment” with respect to, and required by the terms of, any Indebtedness of the Issuer or any of its Restricted Subsidiaries permitted to be incurred under the terms of this Indenture.

 

Section 4.08

Limitation on Dividends and Other Payment Restrictions Affecting Restricted Subsidiaries.

(a) The Issuer will not, and will not permit any Restricted Subsidiary to, directly or indirectly, create or otherwise cause or become effective any consensual encumbrance or restriction of any kind on the ability of any Restricted Subsidiary to:

(1) pay dividends, in cash or otherwise, or make any other distributions on or in respect of its Capital Stock or any other interest or participation in, or measured by, its profits;

(2) pay any Indebtedness owed to the Issuer or any other Restricted Subsidiary;

(3) make loans or advances to the Issuer or any other Restricted Subsidiary; or

(4) transfer any of its properties or assets to the Issuer or any other Restricted Subsidiary.

(b) Section 4.08(a) hereof will not apply to:

(1) encumbrances and restrictions existing under or by reason of the Notes, this Indenture or the Guarantees;

(2) encumbrances and restrictions existing under or by reason of (i) any agreement or instrument relating to, or entered into in connection with, any Project, any Project Obligations, any Permitted Project Undertaking, any Permitted Business Investment, any Permitted Transaction, or any Non-Recourse Financing, in each case that is not prohibited by this Indenture, or (ii) any Project Document;

 

90


(3) any encumbrance or restriction arising pursuant to an agreement or instrument relating to any Indebtedness, Disqualified Stock or Preferred Stock permitted to be incurred or issued subsequent to the Issue Date pursuant to Section 4.09 hereof if (i) such encumbrance or restriction will not materially impair the ability of the Issuer and the Guarantors, taken as a whole, to make anticipated principal or interest payments on the Notes (as determined in good faith by the Issuer), (ii) such encumbrances and restrictions are not materially more disadvantageous, taken as a whole, to the holders of the Notes than is customary in comparable financings for similarly situated issuers (as determined in good faith by the Issuer), or (iii) such encumbrances and restrictions apply only during the continuance of a default in respect of a payment or financial maintenance covenant relating to such Indebtedness, Disqualified Stock or Preferred Stock;

(4) any agreement or instrument in effect on the Issue Date, including pursuant to the Existing Notes, the Existing Indentures and the guarantees thereof;

(5) with respect to restrictions or encumbrances referred to in clause (a)(4) of this Section 4.08, encumbrances and restrictions: (i) that restrict in a customary manner the subletting, assignment or transfer of any properties or assets that are subject to a lease, license, conveyance or other similar agreement to which the Issuer or any Restricted Subsidiary is a party; and (ii) contained in Finance Lease Obligations, purchase money obligations or operating leases that impose such restrictions or encumbrances on the property so purchased, leased, expanded, constructed, developed, installed, replaced, relocated, renewed, maintained, upgraded, repaired or improved;

(6) encumbrances or restrictions contained in any agreement or other instrument of (i) a Person acquired by or merged, amalgamated or consolidated with or into the Issuer or any Restricted Subsidiary in effect at the time of such acquisition, merger, amalgamation or consolidation, as applicable or (ii) an Unrestricted Subsidiary, at the time it is designated or deemed to become a Restricted Subsidiary, in each case, which encumbrance or restriction is not applicable to any Person, or the properties or assets of any Person, other than the Person, or the property or assets of the Person, and was not put in place in contemplation of such event;

(7) encumbrances or restrictions contained in contracts for sales of Capital Stock or assets that are not prohibited by Section 4.10 with respect to the assets or Capital Stock to be sold pursuant to such contract or in customary merger or acquisition agreements (or any option to enter into such contract) for the purchase or acquisition of Capital Stock or assets or any of the Issuer’s Subsidiaries by another Person;

(8) encumbrances or restrictions existing under or by reason of applicable law, regulation or similar restriction or by governmental licenses, concessions, franchises or permits;

(9) encumbrances or restrictions on cash or other deposits or net worth imposed by customers under contracts entered into the ordinary course of business;

 

91


(10) customary provisions in joint venture agreements and other similar agreements or arrangements relating to such joint venture (as determined by the Issuer in good faith);

(11) in the case of clause (a)(4) of this Section 4.08, customary encumbrances or restrictions in connection with purchase money obligations, mortgage financings, Finance Lease Obligations and Sale and Leaseback Transactions;

(12) any encumbrance or restriction arising by reason of customary non-assignment provisions;

(13) customary restrictions on fiduciary cash held by the Issuer’s Restricted Subsidiaries;

(14) customary provisions contained in leases, sub-leases, licenses, sub-licenses or similar agreements, including with respect to intellectual property and other agreements;

(15) customary restrictions on the transfer of non-cash assets contained in power purchase agreements and similar agreements;

(16) [reserved];

(17) customary provisions in agreements governing Hedging Obligations;

(18) customary provisions contained in agreements entered into in the ordinary course of business or encumbrances or restrictions existing under or by reason of any Lien permitted to be incurred pursuant to Section 4.12;

(19) encumbrances or restrictions contained in the charter, partnership agreement or limited liability company agreement or other governing documents of a Restricted Subsidiary relating to tax equity or similar financings;

(20) any encumbrance or restriction pursuant to an agreement or instrument effecting a refunding, renewal, replacement or refinancing of Indebtedness incurred pursuant to, or that otherwise extends, renews, refunds, increases, supplements, modifies, refinances or replaces, an agreement, contract, obligation or instrument referred to in clauses (1) through (19) of this Section 4.08(b) or contained in any amendment, supplement or other modification to an agreement referred to in clauses (1) through (19) of this Section 4.08(b); provided, however, that the encumbrances and restrictions with respect to such Restricted Subsidiary contained in any such agreement or instrument (i) are not materially more restrictive, taken as a whole, with respect to such dividend and other payment restrictions than those contained in such agreement or instrument or (ii) will not materially impair the ability of the Issuer and the Guarantors, taken as a whole, to make anticipated principal or interest payments on the Notes (as determined in good faith by the Issuer); or

(21) restrictions created in connection with any Permitted Receivables Financing.

 

92


For purposes of determining compliance with this Section 4.08, (1) the priority of any Preferred Equity in receiving dividends or distributions prior to dividends or distributions being paid on common stock will not be deemed a restriction on the ability to make distributions on Capital Stock and (2) the subordination of loans or advances made to the Issuer or a Restricted Subsidiary to other Indebtedness incurred by the Issuer or any such Restricted Subsidiary will not be deemed a restriction on the ability to make loans or advances.

Section  4.09 Limitation on Indebtedness, Disqualified Stock and Preferred Equity

(a) Subject to the exceptions in Section 4.09(b), the Issuer will not, and will not permit any of its Restricted Subsidiaries to, directly or indirectly, create, incur, issue, assume, guarantee or otherwise become directly or indirectly liable, contingently or otherwise, with respect to (collectively, “incur”) any Indebtedness (including Acquired Debt), and the Issuer will not issue any Disqualified Stock and will not permit any Restricted Subsidiary to issue any Disqualified Stock or any Restricted Subsidiary that is not a Guarantor to issue Preferred Equity; provided, however, that any Recourse Person may incur Indebtedness (including Acquired Debt) or issue Disqualified Stock, and any Recourse Person (other than the Issuer) may issue Preferred Equity, if on the date of incurrence or issuance thereof the Holdco Debt Ratio for the applicable Test Period would have been equal to or less than 5.0 to 1.0, determined on a pro forma basis (including a pro forma application of the net proceeds therefrom), as if the additional Indebtedness had been incurred or the Disqualified Stock or the Preferred Equity had been issued, as the case may be, on the first day of the relevant Test Period.

(b) Section 4.09(a) will not prohibit the incurrence of any of the following items of Indebtedness (collectively, “Permitted Debt”):

(1) Indebtedness of the Issuer or any of its Restricted Subsidiaries under Credit Facilities; provided that, immediately after giving effect to any such incurrence or issuance (including pro forma application of the net proceeds therefrom), the aggregate principal amount of all such Indebtedness pursuant to this clause (1) and that is then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (1) and then outstanding) does not exceed the greater of (A) $2.0 billion and (B) 60.0% of Distributable Cash for the applicable Test Period;

(2) the incurrence by the Issuer and any Guarantor of Indebtedness represented by the Notes (including any Guarantee thereof) (other than any Additional Notes, if any, or Guarantees with respect thereto);

(3) the Existing Indebtedness, including the Existing Notes and the guarantees thereof;

(4) Indebtedness, Disqualified Stock or Preferred Equity of the Issuer or its Restricted Subsidiaries represented by Finance Lease Obligations, Sale and Leaseback Transactions, mortgage financings or purchase money obligations, or, incurred to finance or refinance the acquisition, purchase, leasing, development, construction, repair, replacement, refurbishment, repositioning, design, installment or improvement of property (real or personal), equipment, or other assets (including Capital Stock), and whether

 

93


acquired through the direct acquisition of such property or assets or the acquisition of the Capital Stock of any Person owning such property or assets, in an aggregate outstanding principal amount as of the date of any incurrence pursuant to this clause (4) which, when taken together with the principal amount of all other Indebtedness incurred pursuant to this clause (4) and that is then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (4) and then outstanding), will not exceed the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

(5) (i) Indebtedness of the Issuer owing to any of its Restricted Subsidiaries or Indebtedness of any of its Restricted Subsidiaries owing to the Issuer or any other Restricted Subsidiary of the Issuer; provided that any such Indebtedness of the Issuer or a Guarantor owing to a Restricted Subsidiary that is not a Guarantor shall be subordinated in right of payment to the Notes; and provided further,(A) any subsequent issuance or transfer of Equity Interests that results in any such Indebtedness being held by a Person other than the Issuer or a Restricted Subsidiary and (B) any transfer of such Indebtedness to a Person that is not the Issuer or a Restricted Subsidiary will be deemed, in each case, to constitute an incurrence of such Indebtedness by the Issuer or such Restricted Subsidiary, as the case may be, that was not permitted by this clause (5); and (ii) in connection with any Indebtedness permitted by subclause (i), any such Indebtedness that is secured by a Lien on any assets or property that is required to be pledged as collateral in order to obtain or maintain any Non-Recourse Financing shall be permitted and such Indebtedness and Lien may be assigned or transferred to third party lenders providing such Non-Recourse Financing;

(6) the issuance by any of the Issuer’s Restricted Subsidiaries to the Issuer or to any of its Restricted Subsidiaries of shares of Preferred Equity; provided, however, that (A) any subsequent issuance or transfer of Equity Interests that results in any such Preferred Equity being held by a Person other than the Issuer or a Restricted Subsidiary of the Issuer, and (B) any sale or other transfer of any such Preferred Equity to a Person that is not either the Issuer or a Restricted Subsidiary of the Issuer, will be deemed, in each case, to constitute an issuance of such Preferred Equity by such Restricted Subsidiary that was not permitted by this clause (6);

(7) (x) Indebtedness or Disqualified Stock incurred or issued by the Issuer or a Restricted Subsidiary to finance an acquisition or Investment or (y) Indebtedness, Disqualified Stock or Preferred Equity of a Restricted Subsidiary incurred and outstanding on the date on which such Restricted Subsidiary was directly or indirectly acquired by the Issuer or a Restricted Subsidiary after the Issue Date or on the date it otherwise becomes a Restricted Subsidiary; provided that if, in the case of clause (x), such Indebtedness, Disqualified Stock is incurred or issued by a Recourse Person or is otherwise recourse to a Recourse Person, or in the case of clause (y), such Restricted Subsidiary is a Recourse Person or such Indebtedness, Disqualified Stock or Preferred Equity is otherwise recourse to a Recourse Person, then in each such case after giving pro forma effect to such incurrence, issuance or acquisition, as applicable, either (A) the Issuer would be permitted to incur at least $1.00 of additional Indebtedness pursuant to the Holdco Debt Ratio test set forth in Section 4.09(a) or (B) the Holdco Debt Ratio for the applicable Test Period would

 

94


be equal to or less than immediately prior to such acquisition and incurrence; and provided further, that Indebtedness, Disqualified Stock or Preferred Equity incurred or issued under this clause (7) in contemplation of such transaction will only be permitted if (i) such Restricted Subsidiary becomes a Guarantor to the extent required to do so pursuant to Section 4.16 or (ii) such Restricted Subsidiary is a Non-Recourse Subsidiary;

(8) Indebtedness of the Issuer and its Restricted Subsidiaries incurred in respect of worker’s compensation claims or claims arising under similar legislation, self-insurance or similar obligations, performance, surety and similar bonds and performance and completion guarantees provided by the Issuer and its Restricted Subsidiaries in the ordinary course of business, or consistent with past practice or industry norms (including, for the avoidance of doubt, incurred in connection with the development, financing (including refinancing), engineering, procurement, construction, commissioning, completion, operation, maintenance or insuring of any Project by any Subsidiary or any related activities to the extent incurred prior to the date of any Non-Recourse Financing by such Project);

(9) Indebtedness, Disqualified Stock and Preferred Stock of the Issuer and its Restricted Subsidiaries providing for indemnification, payment obligations in respect of any non-compete, consulting or similar arrangement, adjustment of purchase price, deferred purchase price (including adjustments thereof, contingent obligations, earn-outs and similar obligations) or progress payments for property or services, or other similar adjustments or obligations in connection with the acquisition or disposition of any business, assets or Capital Stock of a Subsidiary of the Issuer after the Issue Date;

(10) Indebtedness consisting of cash management obligations, netting services, overdraft protection and similar arrangements incurred in the ordinary course of business;

(11) (i) advance payments received from customers for goods and services purchased and credit periods in the ordinary course of business, and (ii) trade or other similar Indebtedness incurred in the ordinary course of business, which is (x) not more than ninety (90) days past due or (y) being contested in good faith and by appropriate proceedings;

(12) Indebtedness constituting reimbursement obligations with respect to letters of credit, bankers’ acceptances, discounted bills of exchange or the discounting or factoring of receivables or payables for credit management purposes, or similar instruments or obligations, in each case incurred or issued in the ordinary course of business or consistent with past practice or industry norms;

(13) Indebtedness in respect of (i) cash pooling arrangements, (ii) Bank Product Obligations and (iii) Hedging Obligations (other than Hedging Obligations incurred for speculative purposes);

 

95


(14) the guarantee by (i) the Issuer or a Restricted Subsidiary of Indebtedness (other than any Non-Recourse Financing) that is permitted to be incurred pursuant to another provision of this Section 4.09; provided that if the Indebtedness being guaranteed is subordinated to or pari passu with the Notes, then the guarantee will be subordinated or pari passu, as applicable, to the same extent as the Indebtedness guaranteed; and (ii) any Non-Recourse Subsidiary of Indebtedness of any other Non-Recourse Subsidiary to the extent such Indebtedness constitutes a Non-Recourse Financing after giving effect to such guarantee;

(15) Indebtedness in connection with any Permitted Receivables Financing;

(16) Indebtedness that constitutes Non-Recourse Financing that is incurred by a Non-Recourse Subsidiary and any Disqualified Stock and Preferred Equity issued by a Non-Recourse Subsidiary (including Disqualified Stock and Preferred Equity outstanding at the time such Non-Recourse Subsidiary becomes a Restricted Subsidiary);

(17) the guarantee by, or any other credit support from, a Recourse Person of any Non-Recourse Financing; provided that the aggregate principal amount of all Indebtedness incurred under this clause (17) and then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (17) and then outstanding) does not exceed the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

(18) Indebtedness of the Issuer or its Restricted Subsidiaries incurred pursuant to an ECR Transaction;

(19) guarantees by the Issuer or its Restricted Subsidiaries in the ordinary course of business of obligations to suppliers, customers, franchisees and licensees;

(20) Indebtedness representing deferred compensation to employees of the Issuer or any of its Restricted Subsidiaries;

(21) Indebtedness consisting of the financing of insurance premiums or take-or-pay obligations contained in supply agreements, in each case, in the ordinary course of business;

(22) Indebtedness, Disqualified Stock or Preferred Equity of the Issuer or any of its Restricted Subsidiaries in an aggregate outstanding principal amount as of the date of any incurrence pursuant to this clause (22) which, when taken together with the principal amount of all other Indebtedness incurred pursuant to this clause (22) and then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (22) that is then outstanding), will not exceed the greater of (A) $250 million and (B) 7.5% of Distributable Cash for the applicable Test Period;

(23) the guarantee by, or any other credit support from, the Issuer or any of its Restricted Subsidiaries of Indebtedness of any Unrestricted Subsidiary or any Joint Venture; provided that the aggregate principal amount of all Indebtedness incurred by any Recourse Person under this clause (23) and then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (w) and then outstanding) does not exceed the greater of (A) $500 million and (B) 15.0% of Distributable Cash for the applicable Test Period;

 

96


(24) any Refinancing Indebtedness incurred with respect to the refinancing of any Indebtedness permitted under Section 4.09(a) or clauses (1), (2), (3), (4), (7), (17), (22), (23), this (24), (25) or (30) of this Section 4.09(b);

(25) Indebtedness, Disqualified Stock and Preferred Stock represented by Management Advances;

(26) Indebtedness, Disqualified Stock or Preferred Equity of the Issuer or any Restricted Subsidiary in an aggregate principal amount or liquidation preference at any time outstanding, together with Refinancing Indebtedness in respect thereof incurred or issued pursuant to clause (x) above, not greater than 100.0% of the net cash proceeds received by the Issuer and the Restricted Subsidiaries since immediately after the Reference Date from the issue or sale of Equity Interests of the Issuer or any Parent Entity (which proceeds are contributed to the Issuer or a Restricted Subsidiary) or cash contributed to the capital of the Issuer (in each case other than proceeds of Disqualified Stock or sales of Equity Interests to, or contributions received from, the Issuer or any of its Subsidiaries) to the extent such net cash proceeds or cash have not been applied to make Restricted Payments or to make other Investments, payments or exchanges pursuant to Section 4.07(b) or to make Permitted Investments (other than Permitted Investments specified in clauses (1) and (2) of the definition thereof) and are not included in Incremental Funds;

(27) any Indebtedness representing Project Obligations or Permitted Project Undertakings;

(28) Indebtedness, Disqualified Stock and Preferred Stock incurred by the Issuer or any of its Restricted Subsidiaries to the extent that the net proceeds thereof are promptly deposited with the Trustee to satisfy or discharge the Notes or exercise the Issuer’s legal defeasance or covenant defeasance, in each case, in accordance with this Indenture;

(29) Indebtedness, Disqualified Stock and Preferred Stock arising from Permitted Intercompany Activities; and

(30) Indebtedness of the Issuer or any Guarantor that is unsecured and is expressly subordinated in right of payment to the Notes; provided that the aggregate principal amount of all such Indebtedness incurred pursuant to this clause (30) and that is then outstanding (and any Refinancing Indebtedness in respect of Indebtedness originally incurred pursuant to this clause (30) and then outstanding) shall not exceed the greater of (A) $1.0 billion and (B) 30.0% of Distributable Cash for the applicable Test Period.

For purposes of this Indenture, no Indebtedness will be deemed to be contractually subordinated in right of payment to any other Indebtedness of the Issuer or the Guarantors solely by virtue of being unsecured or by virtue of being secured on a junior priority basis.

For purposes of determining compliance with this Section 4.09, in the event that an item of proposed Indebtedness meets the criteria of more than one of the categories described in paragraphs (b)(1) through (30) of this Section 4.09, or is entitled to be incurred in whole or in part pursuant to paragraph (a) of this Section 4.09, the Issuer will be permitted to divide and classify

 

97


such item of Indebtedness on the date of its incurrence and later divide and reclassify all or a portion of such item of Indebtedness, in any manner that complies with this Section 4.09; for the avoidance of doubt, any incurrence of Indebtedness may, if applicable, be classified in part as being incurred and outstanding under the first paragraph of this covenant and in part as being incurred and outstanding under one or more categories of Permitted Debt.

(c) For purposes of determining compliance with this Section 4.09, (1) guarantees of, or obligations in respect of letters of credit, bankers’ acceptances or other similar instruments relating to, or Liens securing, Indebtedness, Disqualified Stock or Preferred Stock that is otherwise included in the determination of a particular amount of Indebtedness, Disqualified Stock or Preferred Stock shall not be included, and (2) if obligations in respect of letters of credit, bankers’ acceptances or other similar instruments are incurred pursuant to any Credit Facility and are being treated as incurred pursuant to any clause of Section 4.09(b) or Section 4.09(a) and the letters of credit, bankers’ acceptances or other similar instruments relate to other Indebtedness, Disqualified Stock or Preferred Stock, then such other Indebtedness, Disqualified Stock or Preferred Stock shall not be included.

The accrual of interest or Preferred Equity dividends, the accretion or amortization of original issue discount, the payment of interest on any Indebtedness in the form of additional Indebtedness with the same terms, the reclassification of Preferred Equity as Indebtedness due to a change in accounting principles, and the payment of dividends on Preferred Equity or Disqualified Stock in the form of additional shares of the same class of Preferred Equity or Disqualified Stock will not be deemed to be an incurrence of Indebtedness or an issuance of Preferred Equity or Disqualified Stock for purposes of this Section 4.09. For purposes of determining compliance with any U.S. dollar-denominated restriction on the incurrence of Indebtedness, the U.S. dollar-equivalent principal amount of Indebtedness denominated in a foreign currency shall be utilized, calculated based on the relevant currency exchange rate in effect on the date such Indebtedness was incurred. Notwithstanding any other provision of this Section 4.09, the maximum amount of Indebtedness that the Issuer or any Restricted Subsidiary may incur pursuant to this Section 4.09 shall not be deemed to be exceeded solely as a result of fluctuations in exchange rates or currency values. In the case of any Refinancing Indebtedness, when measuring the outstanding amount of such Indebtedness, such amount shall not include the aggregate amount of accrued and unpaid interest, dividends, premiums (including tender premiums), defeasance costs, underwriting discounts, fees, costs and expenses (including original issue discount, upfront fees or similar fees) in connection with such refinancing.

The amount of any Indebtedness outstanding as of any date will be:

(1) the accreted value of the Indebtedness, in the case of any Indebtedness issued with original issue discount;

(2) the principal amount of the Indebtedness, in the case of any other Indebtedness; and

(3) in respect of Indebtedness of another Person secured by a Lien on the assets of the specified Person, the lesser of:

 

98


(A) the Fair Market Value of such assets at the date of determination; and

(B) the amount of the Indebtedness of the other Person.

Section  4.10 Limitation on Sales of Assets.

(a) The Issuer will not, and will not permit any of its Restricted Subsidiaries to, directly or indirectly, consummate an Asset Sale unless:

(1) the Issuer (or the relevant Restricted Subsidiary, as the case may be) receives consideration at the time of the Asset Sale at least equal to the Fair Market Value of the assets or Equity Interests issued or sold or otherwise disposed of (as determined in good faith by the Issuer at the time of contractually agreeing to such Asset Sale);

(2) at least 75% of the consideration received in the Asset Sale, calculated on a cumulative basis, by the Issuer or such Restricted Subsidiary is in the form of cash or Cash Equivalents. For purposes of this provision, each of the following will be deemed to be cash:

(A) any liabilities, as recorded on the balance sheet of the Issuer or any Restricted Subsidiary (contingent or otherwise), that are assumed or discharged by the transferee (or a third party in connection with such transfer) of any such assets and as a result of which the Issuer and its Restricted Subsidiaries are no longer obliged with respect to such liabilities or are indemnified against further liabilities;

(B) any securities, notes or other obligations received by the Issuer or any such Restricted Subsidiary from such transferee that are converted by the Issuer or such Restricted Subsidiary into cash or Cash Equivalents within 180 days following the closing of the Asset Sale, to the extent of the cash or Cash Equivalents received in that conversion;

(C) any Capital Stock of any Person that will become on the date of acquisition thereof a Restricted Subsidiary as a result of such acquisition and that is involved principally in Permitted Businesses or properties and assets (other than cash or any Capital Stock or other security) that will be used in a Permitted Business of the Issuer and its Restricted Subsidiaries;

(D) Indebtedness of any Restricted Subsidiary that is no longer a Restricted Subsidiary as a result of such Asset Sale, to the extent that the Issuer and each other Restricted Subsidiary are released from any guarantee of such Indebtedness in connection with such Asset Sale;

(E) consideration consisting of Indebtedness of the Issuer or any Guarantor received from persons who are not the Issuer or any Restricted Subsidiary;

 

99


(F) any consideration consisting of Equity Interests in an entity (including a Non-Recourse Subsidiary) engaged in a Permitted Business received in connection with the sale or exchange of an Equity Interest in a Restricted Subsidiary so long as after giving effect to such transaction, the entity in which the Equity Interests have been sold or exchanged remains a Restricted Subsidiary, provided that if such Equity Interests sold or exchanged constituted Collateral the Equity Interests received as consideration constitute Collateral subsequent to such sale or exchange; and

(G) any Designated Non-cash Consideration received by the Issuer or such Restricted Subsidiary in such Asset Sale having an aggregate Fair Market Value, taken together with all other Designated Non-cash Consideration received since the Issue Date pursuant to this clause (G) that is at that time outstanding, not to exceed the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period, determined at the time of receipt of such Designated Non-cash Consideration (with the Fair Market Value of each item of Designated Non-cash Consideration being determined as of the date of receipt thereof and without giving effect to subsequent changes in value).

(b) Within 450 days after the receipt of any Net Proceeds from an Asset Sale, the Issuer (or the applicable Restricted Subsidiary, as the case may be) may:

(1) apply an amount of cash up to the Asset Sale Prepayment Percentage of such Net Proceeds (at the option of the Issuer or Restricted Subsidiary):

(A) to redeem Notes on a ratable basis as described in Section 3.07, to purchase Notes on a ratable basis through open market purchases (to the extent such purchases are at or above 100% of the principal amount thereof) or to purchase Notes pursuant to an offer to all Holders at a purchase price equal to at least 100% of the principal amount thereof, plus accrued and unpaid interest, if any, to (but not including) the date of purchase in accordance with Article 3 (a “Notes Offer”), which Notes Offer will constitute an application of the Asset Sale Prepayment Percentage of such Net Proceeds pursuant to this clause to the extent of the amount of the Notes Offer, whether or not any Notes are tendered;

(B) to the extent such Net Proceeds are from an Asset Sale of Collateral or other assets of a Recourse Person, to repurchase, prepay, redeem or repay: (i) Indebtedness of a Recourse Person that is not the Issuer or a Guarantor (other than Indebtedness owed to the Issuer or a Restricted Subsidiary), or (ii) First Lien Obligations (other than the Notes), and in the case of revolving obligations, to correspondingly reduce commitments with respect thereto; provided that in the case of clause (ii), a pro rata portion of such amount of cash is applied to redeem Notes on a ratable basis as described in Section 3.07 purchase Notes on a ratable basis through open market purchases (to the extent such purchases are at or above 100% of the principal amount thereof) or to make a Notes Offer, which Notes Offer will constitute an application of such amount of cash pursuant to this clause to the extent of the amount of the Notes Offer, whether or not any Notes are tendered;

 

100


(C) to the extent such Net Proceeds are from an Asset Sale that does not constitute Collateral or other assets of a Recourse Person: (i) to make an Investment in, or to acquire all or substantially all of the assets of, or any Capital Stock of, any Permitted Business, if, after giving effect to any such acquisition of Capital Stock, the Permitted Business is or becomes a Restricted Subsidiary (including a Non- Recourse Subsidiary), (ii) to make capital expenditures, (iii) to acquire other assets (other than Capital Stock) that are used or useful in any Project or Permitted Business, (iv) to reduce, prepay, repay or purchase any Indebtedness secured by a Lien on such asset (and terminate the related commitments if such Indebtedness is revolving Indebtedness), (v) to repurchase, prepay, redeem or repay Indebtedness of a Restricted Subsidiary that is not a Guarantor (other than Indebtedness owed to the Issuer or another Restricted Subsidiary), (vi) to repurchase, prepay, redeem or repay Senior Indebtedness (other than the Notes); provided that, in the case of this clause (vi) a pro rata portion of such amount of cash is applied to redeem Notes on a ratable basis as described under Section 3.07, purchase Notes on a ratable basis through open market purchases (to the extent such purchases are at or above 100% of the principal amount thereof) or to make a Notes Offer, which Notes Offer will constitute an application of such amount of cash pursuant to this clause to the extent of the amount of the Notes Offer, whether or not any Notes are tendered, or (vii) to repurchase, prepay, redeem or repay any Non-Recourse Financing or Indebtedness incurred pursuant to any ECR Transaction; or

(D) any combination of the foregoing; or

(2) enter into a binding commitment to apply the Asset Sale Prepayment Percentage of such Net Proceeds pursuant to clauses (1)(C)(i), (ii) or (iii) of this Section 4.10(b); provided that such binding commitment will be treated as a permitted application of the Asset Sale Prepayment Percentage of such Net Proceeds from the date of such commitment until the earlier of: (x) the date on which such acquisition or expenditure is consummated; and (y) the 180th day following the expiration of the aforementioned 450-day period.

Pending the final application of any Asset Sale Prepayment Percentage of such Net Proceeds, the Issuer (or any applicable Restricted Subsidiary) may temporarily reduce Indebtedness (including under any Credit Facility) or otherwise invest the Asset Sale Prepayment Percentage of such Net Proceeds in any manner that is not prohibited by this Indenture.

(c) Any Net Proceeds from Asset Sales (other than Retained Asset Sale Proceeds) of Collateral that are not applied or invested as provided in Section 4.10(b) hereof will constitute “Collateral Excess Proceeds.” When the aggregate amount of Collateral Excess Proceeds exceeds the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period, within ten Business Days thereof, the Issuer will make an offer (a “Collateral Asset Sale Offer”) to all Holders on a pro rata basis and may make an offer to all holders of other First Lien Obligations to purchase, prepay or redeem the maximum principal amount of Notes on a pro rata basis and such other First Lien Obligations (plus all accrued interest on the Indebtedness and the amount of all fees and expenses, including premiums, incurred in connection therewith) that may be purchased, prepaid or redeemed out of the Collateral Excess Proceeds. The offer price for the

 

101


Notes in any Collateral Asset Sale Offer will be equal to 100% of the principal amount, plus accrued and unpaid interest to the date of purchase, prepayment or redemption, subject to the rights of Holders on the relevant record date to receive interest due on the relevant Interest Payment Date, and will be payable in cash. If any Collateral Excess Proceeds remain after consummation of a Collateral Asset Sale Offer (“Declined Collateral Excess Proceeds”), the Issuer may use those Declined Collateral Excess Proceeds for any purpose not otherwise prohibited by this Indenture. If the aggregate principal amount of Notes and other Additional First Lien Obligations tendered into (or to be prepaid or redeemed in connection with) such Collateral Asset Sale Offer exceeds the amount of Collateral Excess Proceeds or if the aggregate amount of the Notes tendered pursuant to a Notes Offer exceeds the amount of the Net Proceeds so applied, such Notes and such other First Lien Obligations, if applicable, will be purchased on a pro rata basis, based on the amounts tendered or required to be prepaid or redeemed (with such adjustments as may be deemed appropriate by the Issuer so that only Notes in denominations of $2,000, or an integral multiple of $1,000 in excess thereof, will be purchased). Upon completion of each Collateral Asset Sale Offer, the amount of Collateral Excess Proceeds will be reset at zero. The Issuer may satisfy the foregoing obligations with respect to any Net Proceeds from an Asset Sale by making a Collateral Asset Sale Offer with respect to such Net Proceeds prior to the time period that may be required by this Indenture with respect to all or a part of the available Net Proceeds (the “Collateral Advance Portion”) in advance of being required to do so by this Indenture (a “Collateral Advance Offer”).

(d) Any Net Proceeds from Asset Sales (other than Retained Asset Sale Proceeds) that do not constitute Collateral that are not applied or invested as provided in Section 4.10(b) hereof will constitute “Excess Proceeds.” When the aggregate amount of Excess Proceeds exceeds the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period, within ten Business Days thereof, the Issuer will make an offer (an “Asset Sale Offer”) to all Holders on a pro rata basis and may make an offer to all holders of other Senior Indebtedness to purchase, prepay or redeem the maximum principal amount of Notes on a pro rata basis and such other Senior Indebtedness (plus all accrued interest on the Indebtedness and the amount of all fees and expenses, including premiums, incurred in connection therewith) that may be purchased, prepaid or redeemed out of the Excess Proceeds. The offer price for the Notes in any Asset Sale Offer will be equal to 100% of the principal amount, plus accrued and unpaid interest to the date of purchase, prepayment or redemption, subject to the rights of Holders on the relevant record date to receive interest due on the relevant Interest Payment Date, and will be payable in cash. If any Excess Proceeds remain after consummation of an Asset Sale Offer (“Declined Non-Collateral Excess Proceeds” and, together with the Declined Collateral Excess Proceeds, “Declined Excess Proceeds”), the Issuer may use those Declined Non-Collateral Excess Proceeds for any purpose not otherwise prohibited by this Indenture. If the aggregate principal amount of Notes and other Senior Indebtedness tendered into (or to be prepaid or redeemed in connection with) such Asset Sale Offer exceeds the amount of Excess Proceeds or if the aggregate amount of the Notes tendered pursuant to a Notes Offer exceeds the amount of the Net Proceeds so applied, such Notes and such other Senior Indebtedness, if applicable, will be purchased on a pro rata basis, based on the amounts tendered or required to be prepaid or redeemed (with such adjustments as may be deemed appropriate by the Issuer so that only Notes in denominations of $2,000, or an integral multiple of $1,000 in excess thereof, will be purchased). Upon completion of each Asset Sale Offer, the amount of Excess Proceeds will be reset at zero. The Issuer may satisfy the foregoing obligations with respect to any Net Proceeds from an Asset Sale by making an Asset Sale Offer with respect to such Net Proceeds prior to the time period that may be required by this Indenture with respect to all or a part of the available Net Proceeds (the “Advance Portion”) in advance of being required to do so by this Indenture (a “Advance Offer”).

 

102


(e) The Issuer will comply with the requirements of Rule 14e-1 under the Exchange Act and any other securities laws and regulations thereunder to the extent those laws and regulations are applicable in connection with each repurchase of Notes pursuant to an Asset Sale Offer. To the extent that the provisions of any securities laws or regulations conflict with the provisions of Section 3.09 hereof or this Section 4.10, the Issuer will comply with the applicable securities laws and regulations and will not be deemed to have breached its obligations under Section 3.09 hereof or this Section 4.10 by virtue of such compliance.

(f) The provisions of Section 3.09 and this Section 4.10 may be waived or modified with the written consent of the Holders of a majority in aggregate principal amount of all the then outstanding Notes.

Section 4.11 Limitation on Transactions with Affiliates.

(a) The Issuer will not, and will not permit any Restricted Subsidiary to, directly or indirectly, enter into any transaction or series of related transactions (including, without limitation, the sale, purchase, exchange or lease of assets or property or the rendering of any service) with, or for the benefit of, any Affiliate of the Issuer or any Restricted Subsidiary involving aggregate payments or consideration in excess of the greater of (A) $75 million and (B) 2.0% of Distributable Cash for the applicable Test Period (each, an “Affiliate Transaction”), unless:

(1) such transaction or series of transactions is on terms that, taken as a whole, are not materially less favorable to the Issuer or such Restricted Subsidiary, as the case may be, than those that would have been obtained in a comparable transaction at such time on an arm’s-length basis with third parties that are not Affiliates, or, if in the good faith judgment of the Issuer, no comparable transaction is available with which to compare such Affiliate Transaction, such Affiliate Transaction is otherwise fair to the Issuer or such Restricted Subsidiary from a financial point of view and when such transaction is taken in its entirety; and

(2) with respect to any transaction or series of related transactions involving aggregate payments or the transfer of assets or the provision of services, in each case having a value that exceeds the greater of (A) $150 million and (B) 4.5% of Distributable Cash for the applicable Test Period, the Issuer’s Board of Directors must approve such transaction (including a majority of the disinterested directors).

(b) Notwithstanding the foregoing, the restrictions set forth in Section 4.11(a) will not apply to:

(1) customary directors’ fees and expenses, indemnities and similar arrangements (including the payment of directors’ and officers’ insurance premiums), consulting fees, employee compensation, employee and director bonuses, employment agreements and arrangements or employee benefit arrangements, including stock options or legal fees, as determined in good faith by the Issuer;

 

103


(2) Permitted Investments and Restricted Payments that are permitted by Section 4.07 (including any transaction that would otherwise constitute a Restricted Payment but is expressly excluded from the definition of the term “Restricted Payments”);

(3) any Management Advances and any waiver or transaction with respect thereto;

(4) agreements and arrangements existing on the Issue Date, and the performance by the Issuer or any Restricted Subsidiary of their obligations thereunder and any amendments, modifications, replacements or supplements thereto or similar agreements entered into in the future; provided that any such amendments, modifications, replacements or supplements, taken as a whole, or any such similar agreements, are not more disadvantageous to the Holders in any material respect than the original agreements or arrangements as in effect on the Issue Date (as determined by the Issuer in good faith) or as are not otherwise prohibited by this Section 4.11;

(5) the issuance of securities pursuant to, or for the purpose of the funding of, employment, termination or severance arrangements, stock options and stock ownership plans, as long as the terms thereof are or have been previously approved by the Issuer’s or the relevant Restricted Subsidiary’s Board of Directors;

(6) (i) transactions between or among, or for the benefit of, the Issuer and the Restricted Subsidiaries (or entity that becomes a Restricted Subsidiary as a result of such transaction), or between or among Restricted Subsidiaries, and (ii) any merger, amalgamation or consolidation with any Parent Entity, provided that, in the case of this clause (ii), such Parent Entity shall have no material liabilities and no material assets other than cash, Cash Equivalents and the Capital Stock of the Issuer and such merger, amalgamation or consolidation is otherwise not prohibited under this Indenture;

(7) payments to or from, and transactions with, customers, clients, suppliers or purchasers or sellers of goods or services, or transactions otherwise relating to the purchase or sale of goods or services (including any cash management activities related thereto), in each case in the ordinary course of business or consistent with past practice or industry norms, or that are on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable as might reasonably have been obtained at such time from an unaffiliated party, in each case as determined by the Issuer in good faith;

(8) any issuance of Equity Interests (other than Disqualified Stock) of the Issuer;

(9) the pledge of Equity Interests of Unrestricted Subsidiaries;

(10) any contribution to the capital of the Issuer;

(11) transactions with respect to which the Issuer has obtained an opinion as to the fairness to the Issuer and its Restricted Subsidiaries from a financial point of view issued by an accounting, appraisal or investment banking firm of national standing;

 

104


(12) transactions permitted by, and complying with, the provisions of, Article 5;

(13) transactions with (i) Unrestricted Subsidiaries or (ii) Joint Ventures in which the Issuer or a Subsidiary of the Issuer holds or acquires an ownership interest (whether by way of Capital Stock or otherwise) or any partners of any such Joint Venture, in each case entered into in the ordinary course or business or consistent with past practice or industry norms (including, without limitation, any cash management activities related thereto), or that are on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable to the Issuer or the applicable Restricted Subsidiary as might reasonably have been obtained at such time from an unaffiliated party (as determined by the Issuer in good faith);

(14) transactions between the Issuer or any of its Restricted Subsidiaries and any Person that is an Affiliate solely as a result of the ownership by the Issuer or any of the Restricted Subsidiaries of Capital Stock of such Person;

(15) transactions with Persons solely in their capacity as holders of Indebtedness of the Issuer or any of its Restricted Subsidiaries where such Persons are treated no more favorably than holders of Indebtedness of the Issuer or such Restricted Subsidiaries generally;

(16) transactions entered into by (i) an Unrestricted Subsidiary with an Affiliate prior to the time such Unrestricted Subsidiary becomes a Restricted Subsidiary or (ii) a Person acquired by or merged, amalgamated, or consolidated with or into the Issuer or any Restricted Subsidiary prior to the time of such acquisition, merger, amalgamation or consolidation, as applicable;

(17) (i) investments by Affiliates in securities or loans or other Indebtedness of the Issuer or any of its Restricted Subsidiaries (and payment of out-of-pocket expenses incurred by such Affiliates in connection therewith) so long as the investment is being offered by the Issuer or such Restricted Subsidiary generally to other investors on the same or more favorable terms, and (ii) payments to Affiliates in respect of securities or loans or other Indebtedness of the Issuer or any of its Restricted Subsidiaries contemplated in the foregoing subclause (i) or that were acquired from Persons other than the Issuer and its Restricted Subsidiaries, in each case, in accordance with the terms of such securities or loans;

(18) transfers of leases, servitudes or similar assets and the entry into related license agreements, in each case, in the ordinary course of business or consistent with past practice or industry norms;

(19) any lease entered into between the Issuer or any Restricted Subsidiary, as lessee, and any Affiliate of the Issuer, as lessor, in each case entered into in the ordinary course of business or consistent with past practice or industry norms, or that is on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable as might reasonably have been obtained at such time from an unaffiliated party, in each case as determined by the Issuer in good faith;

 

105


(20) any administrative services agreement, operations and maintenance agreement, marketing agreement, charter agreement, shipping agency agreement, reciprocal services agreement, excess capacity offtake agreement (including any sale and purchase agreement entered into in connection therewith) or other similar agreement or arrangement with the VGP Investor or any of its Affiliates relating to, or otherwise entered into in connection with, any Project or Permitted Business, in each case entered into in the ordinary course or business or consistent with past practice or industry norms, or that are on terms, taken as a whole, which are fair to the Issuer or the applicable Restricted Subsidiary or at least as favorable to the Issuer or the applicable Restricted Subsidiary as might reasonably have been obtained at such time from an unaffiliated party, in each case as determined by the Issuer in good faith;

(21) payments by the Issuer or any Restricted Subsidiary (including any payment to any Parent Entity for further payment by such Parent Entity), (A) to reimburse the VGP Investor and any of its Affiliates and designees for any reasonable or customary out-of-pocket costs and expenses incurred in connection with the provision of any management, advisory, consulting or other similar services, and (B) to pay reasonable or customary management, monitoring, consulting and similar fees to the VGP Investor; provided that, in the case of the foregoing subclause (B), no such payments shall be made if an Event of Default shall have occurred and be continuing or would immediately result after giving pro forma effect to such payments (it being agreed that such amounts may accrue, but not be payable in cash during such period; provided that all such accrued amounts (plus accrued interest, if any, with respect thereto) may be payable in cash upon the cure or waiver of such Event of Default);

(22) the existence of, or the performance by the Issuer or any of its Restricted Subsidiaries of its obligations under the terms of, any stockholders agreement (including any registration rights agreement or purchase agreement relating thereto) in effect as of the Issue Date and any amendments, modifications, replacements or supplements thereto or similar agreements entered into in the future; provided that any such amendments, modifications, replacements or supplements, taken as a whole, or any such similar agreements, are not more disadvantageous to the holders of the Notes in any material respect than the original agreements or arrangements as in effect on the Issue Date (as determined by the Issuer in good faith) or as are not otherwise prohibited by this Section 4.11;

(23) any transactions with any Captive Insurance Subsidiary;

(24) any Project Obligations, Permitted Project Undertakings and ECR Transactions;

(25) any Permitted Intercompany Activities, any IPO Reorganization Transactions, any Tax Restructuring, and related transactions; and

(26) sales of accounts receivable, or participations therein, or accounts receivable, royalty or other revenue streams and other rights to payment and any other assets, or other transactions, in connection with any Permitted Receivables Financing.

 

106


Section 4.12 Limitation on Liens.

(a) The Issuer will not, and will not permit any of its Restricted Subsidiaries to create, any Lien upon the whole or any part of the currently owned or after-acquired property of the Issuer or any of its Restricted Subsidiaries or assets (each, a “Subject Lien”) to secure any Indebtedness or any guarantee or indemnity in respect of any Indebtedness (other than Permitted Liens), unless, in the case of any Subject Lien on any asset or property that is not Collateral, the Notes (or a Guarantee in the case of Subject Liens on assets or property of a Guarantor) are equally and ratably secured with (or on a senior basis to, in the case such Subject Lien secures any Subordinated Indebtedness) the Obligations secured by such Subject Lien until such time as such Obligations are no longer secured by such Subject Lien.

(b) Any Lien created for the benefit of the holders of the Notes pursuant to this Section 4.12 shall be deemed automatically and unconditionally released and discharged upon the release and discharge of the Subject Lien that gave rise to the obligation to secure the Notes. In addition, in the event that a Subject Lien is or becomes a Permitted Lien, the Issuer may, at its option and without consent from any holder of the Notes, elect to release and discharge any Lien created for the benefit of the holders pursuant to Section 4.12(a) in respect of such Subject Lien.

(c) With respect to any Lien securing Indebtedness that was permitted to secure such Indebtedness at the time of the Incurrence of such Indebtedness, such Lien shall also be permitted to secure any Increased Amount of such Indebtedness. The “Increased Amount” of any Indebtedness shall mean any increase in the amount of such Indebtedness in connection with any accrual of interest, the accretion of accreted value, the amortization of original issue discount, the payment of interest in the form of additional Indebtedness with the same terms, accretion of original issue discount or liquidation preference and increases in the amount of Indebtedness outstanding solely as a result of fluctuations in the exchange rate of currencies or increases in the value of property securing Indebtedness.

Section 4.13 [Reserved].

Section 4.14 Corporate Existence.

Subject to Article 5 hereof, the Issuer shall do or cause to be done all things necessary to preserve and keep in full force and effect its existence, and the corporate, partnership, limited liability company or other existence of each of its Restricted Subsidiaries, in accordance with the respective organizational documents (as the same may be amended from time to time) of the Issuer or any such Restricted Subsidiary; provided that the Issuer shall not be required to preserve the corporate, partnership or other existence of its Restricted Subsidiaries, if the Issuer in good faith shall determine that the preservation thereof is no longer desirable in the conduct of the business of the Issuer and its Restricted Subsidiaries, taken as a whole. For the avoidance of doubt, the Issuer and its Restricted Subsidiaries will be permitted to change their organizational form.

Section 4.15 Offer to Repurchase Upon Change of Control Triggering Event.

(a) Upon the occurrence of a Change of Control Triggering Event with respect to the Notes, the Issuer will be required to make an offer (a “Change of Control Offer”) to each Holder of Notes to repurchase all or any part (being not less than $2,000 or an integral multiple of $1,000 in excess thereof) of that Holder’s Notes pursuant to the terms set forth in this Section 4.15.

 

107


(b) In the Change of Control Offer, the Issuer will offer a payment in cash (the “Change of Control Payment”) equal to 101% of the aggregate principal amount of Notes repurchased, plus accrued and unpaid interest, if any, on the Notes repurchased to, but not including, the date of purchase (the “Change of Control Payment Date”), subject to the rights of Holders on the relevant record date to receive interest, if any, due on the relevant Interest Payment Date. Within 30 days following any Change of Control Triggering Event, the Issuer will mail, or deliver electronically if the Notes are held at DTC, a notice to each Holder describing the transaction or transactions that constitute the Change of Control Triggering Event and offering to repurchase such Notes on the Change of Control Payment Date specified in the notice, which date will be no earlier than 30 days and no later than 60 days from the date such notice is mailed or electronically delivered, pursuant to the procedures required by this Indenture and described in such notice, except in the case of a conditional Change of Control Offer made in advance of a Change of Control as described below. The Issuer will comply with the requirements of Rule 14e-1 under the Exchange Act and any other securities laws and regulations thereunder to the extent those laws and regulations are applicable in connection with the repurchase of the Notes as a result of a Change of Control Triggering Event. To the extent that the provisions of any securities laws or regulations conflict with this Section 4.15, the Issuer will comply with the applicable securities laws and regulations and will not be deemed to have breached its obligations in this Section 4.15 by virtue of such compliance. The Issuer may rely on any no-action letters issued by the Commission indicating that the staff of the Commission will not recommend enforcement action in the event a tender offer satisfies certain conditions.

(c) On the Change of Control Payment Date, the Issuer will, to the extent lawful:

(1) accept for payment all Notes or portions of Notes properly tendered pursuant to the Change of Control Offer;

(2) deposit with the Paying Agent an amount equal to the Change of Control Payment in respect of all Notes or portions of Notes properly tendered; and

(3) deliver or cause to be delivered to the Trustee the Notes properly accepted together with an Officer’s Certificate stating the aggregate principal amount of Notes or portions of Notes being purchased by the Issuer.

The Paying Agent will promptly deliver to each Holder of Notes properly tendered the Change of Control Payment for such Notes(or, if all the Notes are then in global form, make such payment through the facilities of DTC), and, for any Notes represented by certificated notes, the Trustee will, upon receipt of an Authentication Order, promptly authenticate and mail (or cause to be transferred by book entry) to such Holder a new certificated note representing equal in principal amount to any unpurchased portion of the Notes surrendered, if any; provided that each such new Note will be in a principal amount of not less than $2,000 or an integral multiple of $1,000 in excess thereof. Any Note so accepted for payment will cease to accrue interest on and after the Change of Control Payment Date unless the Issuer defaults in making the Change of Control Payment. The Issuer will publicly announce the results of the Change of Control Offer on or as soon as practicable after the Change of Control Payment Date.

 

108


(d) The provisions described herein that require the Issuer to make a Change of Control Offer following a Change of Control Triggering Event will be applicable regardless of whether any other provisions of this Indenture are applicable.

(e) The Issuer will not be required to make a Change of Control Offer upon a Change of Control Triggering Event if (1) a third party makes the Change of Control Offer in the manner, at the times and otherwise in compliance with the requirements set forth in this Indenture applicable to a Change of Control Offer made by the Issuer and purchases all Notes properly tendered and not withdrawn under the Change of Control Offer, or (2) a notice of redemption with respect to the Notes has been given pursuant to this Indenture as described in Section 3.07 and all conditions to any such redemption shall have been satisfied or waived, unless and until there is a default in payment of the Change of Control Payment. A Change of Control Offer may be made in advance of a Change of Control or a Change of Control Triggering Event, and conditioned upon the occurrence of such Change of Control or Change of Control Triggering Event, if a definitive agreement is in place for a Change of Control at the time of making the Change of Control Offer, Notes repurchased by the Issuer pursuant to a Change of Control Offer will have the status of Notes issued but not outstanding or will be retired and cancelled, at the Issuer’s option. Notes purchased by a third party pursuant to this clause (e) will have the status of Notes issued and outstanding.

The provisions in this Section 4.15 relating to the Issuer’s obligation to make an offer to repurchase the Notes as a result of a Change of Control may be waived or modified with the written consent of the Holders of a majority in aggregate principal amount of the Notes then outstanding.

The Trustee shall have no obligation to determine whether a Change of Control Triggering Event or any component thereof has occurred or is continuing, or notify the Holders of a Change of Control Triggering Event.

Section 4.16 Future Guarantees.

If, on any date (a “Guarantee Date”), the aggregate amount of Indebtedness for borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit of any Restricted Subsidiary that is not a Guarantor or a Non-Recourse Subsidiary then outstanding (other than any such Indebtedness owing to the Issuer or any Guarantor) exceeds the greater of (A) $250.0 million and (B) 7.5% of Distributable Cash for the applicable Test Period (tested at the time of incurrence of the applicable Indebtedness without regard to any subsequent change in Distributable Cash), the Issuer will cause such Restricted Subsidiary to (x) execute and deliver to the Trustee, within 45 days after such Guarantee Date, a supplemental indenture to this Indenture, which shall be substantially in the form attached as Exhibit E hereto, pursuant to which such Restricted Subsidiary will unconditionally guarantee the payment of the Notes and all other obligations under the Indenture, jointly and severally with all other Guarantors (if any) of the Notes, and (y) execute and deliver Security Documents or supplements thereto.

 

109


Section 4.17 Designation of Restricted and Unrestricted Subsidiaries.

(a) The Board of Directors of the Issuer may designate any Subsidiary of the Issuer (including any newly acquired or newly formed Subsidiary or a Person becoming a Subsidiary through merger, consolidation or other business combination transaction, or Investment therein), to be an Unrestricted Subsidiary only if:

(1) such Subsidiary or any of its Subsidiaries does not own any Equity Interests or Indebtedness of, or own or hold any Lien on any property of, the Issuer or any other Subsidiary of the Issuer which is not a Subsidiary of the Subsidiary to be so designated or otherwise an Unrestricted Subsidiary; provided that each Subsidiary to be so designated and its Subsidiaries has not at the time of designation, and does not thereafter, create, incur, issue, assume, guarantee or otherwise become directly or indirectly liable with respect to any Indebtedness pursuant to which the lender has recourse to any of the assets of the Issuer or any Restricted Subsidiary (other than Equity Interests in the Unrestricted Subsidiary); and

(2) such designation and the Investment of the Issuer or any of the Restricted Subsidiaries in such Subsidiary complies with Section 4.07.

Any such designation by the Board of Directors of the Issuer shall be evidenced to the Trustee by filing with the Trustee a copy of the resolution of the Board of Directors of the Issuer giving effect to such designation and an Officer’s Certificate certifying that such designation complies with the foregoing conditions.

(b) The Board of Directors of the Issuer may designate any Unrestricted Subsidiary to be a Restricted Subsidiary; provided that immediately after giving effect to such designation (1) no Event of Default would result therefrom and (2) (a) any outstanding Indebtedness of such Unrestricted Subsidiary would be permitted to be incurred by a Restricted Subsidiary under Section 4.09 and shall be deemed to be incurred thereunder, and (b) all Liens encumbering the assets of such Unrestricted Subsidiary would be permitted to be incurred by a Restricted Subsidiary under Section 4.12 and shall be deemed to be incurred thereunder, in each case calculated on a pro forma basis as if such designation had occurred at the beginning of the applicable reference period on a pro forma basis taking into account such designation. Any such designation by the Board of Directors of the Issuer shall be evidenced to the Trustee by promptly filing with the Trustee a copy of the resolution of the Board of Directors giving effect to such designation or an Officer’s Certificate certifying that such designation complied with the foregoing provisions.

Section 4.18 Suspension of Certain Covenants.

If on any date following the Issue Date:

(a) the Notes have an Investment Grade Rating from at least one Rating Agency; and

(b) no Event of Default shall have occurred and be continuing under this Indenture (the occurrence of the events described in the foregoing clause (a) and this clause (b) being collectively referred to as a “Covenant Suspension Event”),

 

110


then, beginning on that day and subject to the provisions of the following paragraph, the covenants of this Indenture under Sections 4.07, 4.08, 4.09, 4.10, 4.11, 4.16, clause (4) of Section 5.01 and Article 12 will be suspended (the “Suspended Covenants”):

During any period that the foregoing covenants have been suspended, the Board of Directors of the Issuer may not designate any of the Issuer’s Subsidiaries as Unrestricted Subsidiaries.

During the Suspension Period, the Issuer and its Restricted Subsidiaries will be entitled to incur Liens to the extent provided for in Section 4.12 (including, without limitation, Permitted Liens). Any Permitted Liens that may refer to one or more Suspended Covenants shall be interpreted as though such applicable Suspended Covenant(s) continued to be applicable during the Suspension Period (but solely for purposes of Section 4.12 and the “Permitted Liens” definition and for no other covenant).

Notwithstanding the foregoing, if a Rating Agency withdraws its ratings or downgrades the ratings assigned to the Notes such that the Notes no longer have an Investment Grade Rating from at least one Rating Agency, the foregoing covenants shall be reinstated as of and from the date of such rating decline (the “Reversion Date”). The period of time between the Covenant Suspension Event and the Reversion Date is referred to in this Indenture as the “Suspension Period”. Any Indebtedness incurred during the Suspension Period (or deemed incurred or issued in connection with a Limited Condition Transaction entered into during the Suspension Period) will be classified as having been incurred pursuant to Section 4.09(b)(3).

Solely with respect to the Notes for which a Covenant Suspension Event has occurred:

(1) Calculations made after the Reversion Date of the amount available to be made as Restricted Payments under Section 4.07 will be made as though Section 4.07 had been in effect since the Issue Date and prior to, but not during, the Suspension Period (including with respect to a Limited Condition Transaction entered into during the Suspension Period). Accordingly, Restricted Payments made during the Suspension Period will not reduce the amount available to be made as Restricted Payments under Section 4.07(a). In addition, all Investments made during the Suspension Period (or deemed made in connection with a Limited Condition Transaction entered into during the Suspension Period) will be classified to have been made under clause (5) of the definition of “Permitted Investments”;

(2) For purposes of Section 4.08, on the Reversion Date, any consensual encumbrances or consensual restrictions of the type specified in clauses (1) through (4) of Section 4.08(a) entered into during the Suspension Period will be deemed to have been in effect on the Issue Date, so that they are permitted under Section 4.08(b)(4);

(3) For purposes of Section 4.11, any Affiliate Transaction entered into after the Reversion Date pursuant to a contract, agreement, loan, advance or guaranty with, or for the benefit of, any Affiliate of the Issuer entered into during the Suspension Period will be deemed to have been in effect as of the Issue Date for purposes of Section 4.11(b)(4);

 

111


(4) For purposes of Section 4.10, the amount of Collateral Excess Proceeds and Excess Proceeds will be reset at zero; and

(5) Notwithstanding that the Suspended Covenants may be reinstated after the Reversion Date, (a) no Default, Event of Default or breach of any kind will be deemed to exist under this Indenture, the Notes or the Guarantees with respect to the Suspended Covenants, and none of the Issuer or any of its Subsidiaries shall bear any liability for any actions taken or events occurring during the Suspension Period, or any actions taken at any time pursuant to any Contractual Obligation arising during any Suspension Period, in each case as a result of a failure to comply with the Suspended Covenants during the Suspension Period (or, upon termination of the Suspension Period or after that time based solely on any action taken or event that occurred during the Suspension Period), and (b) following a Reversion Date, the Issuer and each Restricted Subsidiary will be permitted, without causing a Default or Event of Default, to honor, comply with or otherwise perform any contractual commitments or obligations arising during any Suspension Period and to consummate the transactions contemplated thereby.

Promptly following the occurrence of any Suspension Period or Reversion Date in accordance with this Section 4.18, the Issuer will provide an Officer’s Certificate to the Trustee regarding such occurrence, provided that the failure to so notify the Trustee shall not be a default under this Indenture. The Trustee shall have no obligation to independently determine or verify if a Suspension Period or Reversion Date has occurred or notify the holders of any Suspension Period or Reversion Date. The Trustee may provide a copy of such Officer’s Certificate to any Holder upon request. The Trustee shall have no duty to monitor the ratings of the Notes, and shall not be deemed to have any knowledge of the ratings of the Notes.

ARTICLE 5

SUCCESSORS

Section 5.01 Merger, Consolidation or Sale of Assets.

(a) The Issuer will not, directly or indirectly: (1) consolidate or merge with or into another Person (whether or not the Issuer is the surviving Person); or (2) sell, assign, transfer, convey or otherwise dispose of all or substantially all of the properties or assets of the Issuer and its Subsidiaries, taken as a whole, in one or more related transactions, to another Person; unless:

(1) either: (a) the Issuer is the surviving Person; or (b) the Person formed by or surviving any such consolidation or merger (if other than the Issuer) or to which such sale, assignment, transfer, conveyance or other disposition has been made is a corporation, partnership or limited liability company organized or existing under the laws of the United States, any state of the United States or the District of Columbia;

(2) the Person formed by or surviving any such consolidation or merger (if other than the Issuer) or the Person to which such sale, assignment, transfer, conveyance or other disposition has been made assumes all the obligations of the Issuer under the Security Documents, the Notes and this Indenture pursuant to a supplemental Indenture or other customary documentation;

 

112


(3) immediately after such transaction, no Event of Default exists;

(4) the Issuer, as the case may be, or the Person formed by or surviving any such consolidation or merger (if other than the Issuer), or to which such sale, assignment, transfer, conveyance or other disposition has been made would, on the date of such transaction after giving pro forma effect thereto and any related financing transactions as if the same had occurred at the beginning of the applicable Test Period, (i) be permitted to incur at least $1.00 of additional Indebtedness pursuant to the Holdco Debt Ratio test set forth in Section 4.09(a) or (ii) would have had a Holdco Debt Ratio equal to or less than the actual Holdco Debt Ratio for the applicable Test Period;

(5) the Issuer delivers to the Trustee an Officer’s Certificate and opinion of counsel as to compliance with this Section 5.01(a); and

(6) to the extent any assets of the Person formed by or surviving any such consolidation or merger are assets of the type which would constitute Collateral under the Security Documents, such Person will take such action as may be reasonably necessary to cause such property and assets to be made subject to the Lien of the Security Documents in the manner and to the extent required in this Indenture or any of the Security Documents and shall take all reasonably necessary action required by this Indenture of any of the Security Documents so that such Lien is perfected to the extent required by the Security Documents.

In addition, the Issuer may not, directly or indirectly, lease all or substantially all of its and its respective Subsidiaries’ properties or assets, in one or more related transactions, to any other Person.

This Section 5.01(a) will not apply to (1) a merger of the Issuer with an Affiliate solely for the purpose of reforming the Issuer in another jurisdiction; (2) any sale, transfer, assignment, conveyance, lease or other disposition of assets between or among the Issuer and any Restricted Subsidiary of the Issuer, including by way of merger or consolidation; (3) a conversion by the Issuer into a corporation, partnership, limited partnership, limited liability company or trust organized or existing under the laws of the jurisdiction of organization of the Issuer or the laws of a jurisdiction in the United States (and, if such entity is not a corporation, a co-obligor of the Notes is a corporation organized or existing under such laws); and (4) a change of the Issuer’s name.

(b) Subject to Section 10.04, no Guarantor will, and the Issuer will not permit any Guarantor to, consolidate or merge with or into or wind up into (whether or not such Guarantor is the surviving Person), or sell, assign, transfer, lease, convey or otherwise dispose of all or substantially all of its properties or assets, in one or more related transactions, to any Person unless:

(1) either: (a) such Guarantor is the surviving Person; or (b) the Person formed by or surviving any such consolidation or merger (if other than such Guarantor) or the Person to which such sale, assignment, transfer, conveyance or other disposition has been made assumes all the obligations of such Guarantor under the Security Documents, the Notes, this Indenture and such Guarantor’s related Guarantee pursuant to supplemental indenture or other customary documentation;

 

113


(2) immediately after such transaction, no Event of Default exists;

(3) the Issuer delivers to the Trustee an Officer’s Certificate and an Opinion of Counsel as to compliance with this Section 5.01(b); and

(4) to the extent any assets of the Person formed by or surviving any such consolidation or merger are assets of the type which would constitute Collateral under the Security Documents, such Person will take such action as may be reasonably necessary to cause such property and assets to be made subject to the Lien of the Security Documents in the manner and to the extent required in this Indenture or any of the Security Documents and shall take all reasonably necessary action required by this Indenture of any of the Security Documents so that such Lien is perfected to the extent required by the Security Documents; or

(A) the transaction is not prohibited by Section 4.10(a); or

(B) in the case of assets comprised of Equity Interests of Subsidiaries that are not Guarantors, such Equity Interests are sold, assigned, transferred, leased, conveyed or otherwise disposed of to one or more Restricted Subsidiaries, provided that if such Equity Interests constitute Collateral they will continue to constitute Collateral following such disposition.

This Section 5.01(b) will not apply to (1) a merger of the Guarantor with an Affiliate solely for the purpose of reforming the Guarantor in another jurisdiction, (2) any sale, transfer, assignment, conveyance, lease or other disposition of assets between or among the Issuer or a Guarantor, (3) a conversion by the Guarantor into a corporation, partnership, limited partnership, limited liability company or trust organized or existing under the laws of the jurisdiction of organization of such Guarantor, or (4) a liquidation or dissolution or change of the Guarantor’s legal form if the Issuer determines in good faith that such action is in the best interests of the Issuer, in each case, without regard to the requirements set forth in the preceding paragraph.

Section 5.02 Successor Corporation Substituted

Upon any consolidation or merger, or any sale, assignment, transfer, lease, conveyance or other disposition of all or substantially all of the properties or assets of the Issuer or any Guarantor in a transaction that is subject to, and that complies with the provisions of, Section 5.01 hereof, the successor Person formed by such consolidation or into or with which the Issuer or such Guarantor, as the case may be, is merged or to which such sale, assignment, transfer, lease, conveyance or other disposition is made shall succeed to, and be substituted for (so that from and after the date of such consolidation, merger, sale, assignment, transfer, lease, conveyance or other disposition, the provisions of this Indenture referring to the “Issuer” or such “Guarantor” shall refer instead to the successor Person and not to the Issuer or such Guarantor), and may exercise every right and power of the Issuer or such Guarantor, as the case may be, under this Indenture or the Guarantees, as the case may be, with the same effect as if such successor Person had been named as the Issuer or such Guarantor, as the case may be, herein or the Guarantees, as the case may be. When a

 

114


successor Person assumes all obligations of its predecessor hereunder, the Notes or the Guarantees, as the case may be, such predecessor shall be released from all obligations; provided that in the event of a transfer or lease, the predecessor shall not be released from the payment of principal and interest or other obligations on the Notes or the Guarantees, as the case may be.

ARTICLE 6

DEFAULTS AND REMEDIES

Section 6.01 Events of Default.

Each of the following is an “Event of Default”:

(a) default for 30 days in the payment when due of interest on the Notes;

(b) default in the payment when due of the principal of, or premium, if any, on the Notes;

(c) failure by the Issuer for 180 days after receipt of written notice given by the Trustee to the Issuer or Holders of at least 30% in aggregate principal amount of the Notes then outstanding voting as a single class to the Issuer and the Trustee, to comply with Section 4.03;

(d) failure by the Issuer or any Guarantor for 60 days after receipt of written notice given by the Trustee to the Issuer or Holders of at least 30% in aggregate principal amount of Notes then outstanding voting as a single class to the Issuer and the Trustee, to comply with any of the agreements in this Indenture other than those described in clauses (a), (b) and (c) of this Section 6.01;

(e) default under any mortgage, indenture or instrument under which there is issued or by which there is secured or evidenced any Indebtedness for money borrowed by the Issuer or any Restricted Subsidiary (other than a Non-Recourse Subsidiary), or the payment of which is guaranteed by the Issuer or any Restricted Subsidiary (other than a Non-Recourse Subsidiary), whether such Indebtedness or guarantee now exists, or is created after the Issue Date, if both:

(1) such default either results from the failure to pay principal on such Indebtedness at its stated final maturity (after giving effect to any applicable grace periods) or relates to an obligation other than the obligation to pay principal of any such Indebtedness at its stated final maturity and results in the holder or holders of such Indebtedness causing such Indebtedness to become due prior to its stated final maturity; and

(2) the principal amount of any such Indebtedness, together with the principal amount of any other such Indebtedness in default for failure to pay principal at stated final maturity (after giving effect to applicable grace periods), or the maturity of which has been so accelerated, exceeds the greater of (A) $100 million and (B) 3.0% of Distributable Cash for the applicable Test Period,

 

115


provided that this clause (e) shall not apply to secured Indebtedness that becomes due as a result of the voluntary sale or transfer of the property or assets securing such Indebtedness to a Person that is not an Affiliate of the Issuer;

(f) one or more judgments for the payment of money in an aggregate amount in excess of the greater of (A) $100.0 million and (B) 3.0% of Distributable Cash for the applicable Test Period (excluding therefrom any amount reasonably expected to be covered by insurance) shall be rendered against the Issuer or any Restricted Subsidiary (other than a Non-Recourse Subsidiary) or any combination thereof and the same shall not have been paid, discharged or stayed for a period of 60 days after such judgment became final and non-appealable;

(g) except as permitted by this Indenture, any Guarantee of the Notes shall be held in any final and non-appealable judgment to be unenforceable or invalid or shall cease for any reason to be in full force and effect;

(h) the Issuer or any Guarantor pursuant to or within the meaning of Bankruptcy Law:

(1) commences a voluntary case,

(2) consents to the entry of an order for relief against it in an involuntary case,

(3) consents to the appointment of a custodian of it or for all or substantially all of its property,

(4) makes a general assignment for the benefit of its creditors, or

(5) generally is not paying its debts as they become due;

(i) a court of competent jurisdiction enters an order or decree under any Bankruptcy Law that:

(1) is for relief against the Issuer or any Guarantor in an involuntary case;

(2) appoints a custodian of the Issuer or any Guarantor; or

(3) orders the liquidation of the Issuer or any Guarantor;

and the order or decree remains unstayed and in effect for 60 consecutive days; and

(j) other than by reason of the satisfaction in full of all obligations under this Indenture and discharge of this Indenture with respect to the Notes or the release of the Collateral with respect to the Notes in accordance with the terms of this Indenture and the Security Documents, (i)(A) in the case of any security interest with respect to any material portion of the Collateral, such security interest under the Security Documents shall, at any time, cease to be a valid and perfected security interest or shall be declared invalid or unenforceable except to the extent that any such perfection or priority is not required pursuant to the Security Documents or this Indenture or the Issuer or the relevant Guarantor, as applicable, has delivered all required certificates representing securities pledged under the Security Documents to the Collateral Agent, or (B) in the case of any security

 

116


interest with respect to any material portion of the Collateral, the Issuer or any Guarantor shall assert, in any pleading in any court of competent jurisdiction, that any security interest under any Security Document is invalid or unenforceable, and (ii) such default continues for 30 days after receipt of written notice given by the Trustee to the Issuer or the Holders of not less than 30% in aggregate principal amount of the then outstanding Notes to the Issuer and the Trustee.

Section 6.02 Acceleration.

In the case of an Event of Default specified in clause (h) or (i) of Section 6.01 hereof with respect to the Issuer, all outstanding Notes will become due and payable immediately without further action or notice. If any other Event of Default occurs and is continuing, the Trustee by written notice to the Issuer or the Holders of at least 30% in aggregate principal amount of the then outstanding Notes by written notice to the Issuer and the Trustee, may declare all the Notes to be due and payable immediately. Upon any such declaration, the Notes shall become due and payable immediately.

The Holders of a majority in aggregate principal amount of the then outstanding Notes by written notice to the Issuer and the Trustee, and the Trustee may, on behalf of the Holders of all the Notes, rescind an acceleration and its consequences hereunder, if the rescission would not conflict with any judgment or decree and if all existing Events of Default (except nonpayment of principal of, premium on, if any, or interest, if any, on the Notes that has become due solely because of the declaration of acceleration) have been cured or waived.

In the event of a declaration of acceleration of the Notes because an Event of Default described in clause (e) of Section 6.01 has occurred and is continuing, the declaration of acceleration of the Notes shall be automatically annulled if the default triggering such Event of Default pursuant to such clause (e) of Section 6.01 shall be remedied or cured, or waived by the holders of the Indebtedness with respect to which such default has occurred within 30 days after the declaration of acceleration of the Notes; provided that (a)(1) the annulment of the acceleration of the Notes would not conflict with any judgment or decree of a court of competent jurisdiction and (2) all existing Events of Default, except nonpayment of principal, premium or interest on the Notes that became due solely because of the acceleration of the Notes, have been cured or waived, (b) the Indebtedness or guarantee that is the basis for such Event of Default has been discharged, or (c) the requisite number of holders thereof have rescinded or waived the acceleration, notice or action (as the case may be) giving rise to such Event of Default.

If a Default occurs for a failure to report or deliver a required certificate in connection with another default (an “Initial Default”) then at the time such Initial Default is cured, such Default for a failure to report or deliver a required certificate in connection with the Initial Default will also be cured without any further action and any Default or Event of Default for the failure to comply with the time periods prescribed in Section 4.03 or otherwise to deliver any notice or certificate pursuant to any other provision of this Indenture shall be deemed to be cured upon the delivery of any such report required by such covenant or notice or certificate, as applicable, even though such delivery is not within the prescribed period specified in this Indenture.

 

117


Any notice of an Event of Default, notice of acceleration or instruction to the Trustee to provide a notice of an Event of Default, notice of acceleration or take any other action in connection with an Event of Default and/or acceleration of the Notes (a “Noteholder Direction”) provided by any one or more holders (each a “Directing Holder”) must be accompanied by a written representation from each such holder of Notes delivered to the Issuer and the Trustee that such holder is not (or, in the case such holder is DTC, or its nominee, that such holder is being instructed solely by beneficial owners that have represented to such holder that they are not) Net Short (a “Position Representation”), which representation, in the case of a Noteholder Direction relating to the delivery of a notice of an Event of Default shall be deemed a continuing representation until the resulting Event of Default is cured or otherwise ceases to exist or such Notes are accelerated. In addition, each Directing Holder is deemed, at the time of providing a Noteholder Direction, to covenant to provide the Issuer with such other information as the Issuer may reasonably request from time to time in order to verify the accuracy of such holder’s Position Representation within five Business Days of request therefor (a “Verification Covenant”). In any case in which the holder is DTC, or its nominee, any Position Representation or Verification Covenant required hereunder shall be provided by the beneficial owner of such Notes in lieu of DTC, or its nominee, and DTC shall be entitled to conclusively rely on such Position Representation and Verification Covenant in delivering its direction to the Trustee.

If, following the delivery of a Noteholder Direction, but prior to acceleration of the Notes, the Issuer determines in good faith that there is a reasonable basis to believe a Directing Holder was, at any relevant time, in breach of its Position Representation and provides to the Trustee an Officer’s Certificate stating that the Issuer has initiated litigation in a court of competent jurisdiction seeking a determination that such Directing Holder was, at such time, in breach of its Position Representation, and seeking to invalidate any Event of Default that resulted from the applicable Noteholder Direction, the cure period with respect to such Event of Default shall be automatically stayed and the cure period with respect to such Event of Default shall be automatically reinstituted and any remedy stayed pending a final and non-appealable determination of a court of competent jurisdiction on such matter (a “Court Determination”). If, following the delivery of a Noteholder Direction, but prior to acceleration of the Notes, the Issuer provides to the Trustee an Officer’s Certificate stating that a Directing Holder failed to satisfy its Verification Covenant, the cure period with respect to such Event of Default shall be automatically stayed and the cure period with respect to any Event of Default that resulted from the applicable Noteholder Direction shall be automatically reinstituted and any remedy stayed pending satisfaction of such Verification Covenant, and confirmation of such satisfaction shall be provided in writing by the Issuer to the Trustee. Any breach of the Position Representation (as confirmed by a Court Determination) shall result in such holder’s participation in such Noteholder Direction being disregarded; and, if, without the participation of such noteholder, the percentage of Notes held by the remaining noteholders that provided such Noteholder Direction would have been insufficient to validly provide such Noteholder Direction, such Noteholder Direction shall be void ab initio, with the effect that such Event of Default shall be deemed never to have occurred, acceleration voided and the Trustee shall be deemed not to have received such Noteholder Direction or any notice of such Event of Default; provided, however, that this shall not invalidate any indemnity and/or security provided by any Directing Holder to the Trustee.

Notwithstanding anything in the preceding two paragraphs to the contrary, any Noteholder Direction delivered to the Trustee during the pendency of an Event of Default as the result of a bankruptcy or similar proceeding shall not require compliance with the foregoing paragraphs. For the avoidance of doubt, the Trustee shall be entitled to conclusively rely on any Noteholder

 

118


Direction, Position Representation, Verification Covenant, Officer’s Certificate or other document delivered to it in accordance with this Indenture, shall have no duty to monitor, inquire as to or investigate the accuracy of, or compliance with, any Position Representation or any Verification Covenant, verify any statements in any Officer’s Certificate delivered to it, or otherwise make calculations, investigations or determinations or take any other actions with respect to Derivative Instruments, Net Shorts, Long Derivative Instruments, Short Derivative Instruments or otherwise. The Trustee shall have no liability to the Issuer, any holder or any other Person in acting in good faith pursuant to a Noteholder Direction without regard to any Position Representation or compliance with any Verification Covenant, and all such parties agree not to commence any legal proceedings against the Trustee in respect of, and agree that the Trustee will not be liable for, the delivery and accuracy of, or compliance with, any Position Representation or any Verification Covenant.

With their acquisition of the Notes, each Holder and subsequent purchaser of the Notes consents to the delivery of its Position Representation by the Trustee to the Issuer in accordance with the terms of this Section 6.02.

The Issuer hereby confirms that the indemnification and reimbursement obligations to the Trustee and its agents and counsel as set forth in Section 7.06 shall apply to any actions that the Trustee takes or omits to take in accordance with this Section 6.02.

Section 6.03 Other Remedies.

If an Event of Default occurs and is continuing with respect to the Notes, the Trustee may pursue any available remedy to collect the payment of principal of, premium on, if any, or interest, if any, on the Notes or to enforce the performance of any provision of the Notes or this Indenture.

The Trustee may maintain a proceeding even if it does not possess any of the Notes or does not produce any of them in the proceeding. A delay or omission by the Trustee or any Holder in exercising any right or remedy accruing upon an Event of Default shall not impair the right or remedy or constitute a waiver of or acquiescence in the Event of Default. All remedies are cumulative to the extent permitted by law.

Section 6.04 Waiver of Past Defaults.

The Holders of at least a majority in aggregate principal amount of the then outstanding Notes voting as a class by written notice to the Trustee may, on behalf of the Holders of all of the Notes waive any existing Default or Event of Default and its consequences hereunder, except a continuing Default in the payment of principal of, premium on, if any, or interest, if any, on, any Note held by a non-consenting Holder (including in connection with an offer to purchase); provided, however, that the Holders of a majority in aggregate principal amount of the then outstanding Notes may rescind an acceleration and its consequences, including any related payment default that resulted from such acceleration. Upon any such waiver, such Default shall cease to exist, and any Event of Default arising therefrom shall be deemed to have been cured for every purpose of this Indenture; but no such waiver shall extend to any subsequent or other Default or impair any right consequent thereon.

 

119


Section 6.05 Control by Majority.

Holders of a majority in aggregate principal amount of the then outstanding Notes may direct the time, method and place of conducting any proceeding for exercising any remedy available to the Trustee or the Collateral Agent or exercising any trust or power conferred on it with respect to the Notes. However, the Trustee or the Collateral Agent may refuse to follow any direction that conflicts with law or this Indenture, or that that the Trustee or the Collateral Agent determines may be unduly prejudicial to the rights of other Holders of Notes or that may involve the Trustee or the Collateral Agent in personal liability.

Section 6.06 Limitation on Suits.

Except to enforce the contractual right to receive payment of principal, premium, if any, or interest when due on or after the respective due dates expressed in an outstanding Note, no Holder of a Note may pursue any remedy with respect to this Indenture or the Notes unless:

(a) such Holder has previously given the Trustee written notice that an Event of Default is continuing;

(b) Holders of at least 30% in aggregate principal amount of the then outstanding Notes make a written request to the Trustee to pursue the remedy;

(c) such Holder or Holders offer and, if requested, provide to the Trustee security and/or indemnity reasonably satisfactory to the Trustee against any loss, liability or expense;

(d) the Trustee has not complied with such request within 60 days after receipt of the request and the offer of security or indemnity; and

(e) during such 60-day period, Holders of a majority in aggregate principal amount of the then outstanding Notes do not give the Trustee a direction inconsistent with such written request within such 60 day period.

A Holder may not use this Indenture to prejudice the rights of another Holder or to obtain a preference or priority over another Holder.

Section 6.07 Rights of Holders of Notes to Receive Payment.

Notwithstanding any other provision of this Indenture, the right of any Holder to receive payment of principal of, premium on, if any, or interest, if any, on a Note, on or after the respective due dates expressed in such Note (including in connection with an offer to purchase), or to bring suit for the enforcement of any such payment on or after such respective dates, shall not be impaired or affected without the consent of such Holder.

Section 6.08 Collection Suit by Trustee.

If an Event of Default specified in Section 6.01(a) or (b) hereof occurs and is continuing with respect to the Notes, the Trustee is authorized to recover judgment in its own name and as trustee of an express trust against the Issuer for the whole amount of principal of, premium on, if any, and interest, if any, remaining unpaid on the Notes and interest on overdue principal and, to the extent lawful, interest and such further amount as shall be sufficient to cover the costs and expenses of collection, including the reasonable compensation, expenses, disbursements and advances of the Trustee, the Agents and their respective agents and counsel.

 

120


If the Trustee or any Holder has instituted any proceeding to enforce any right or remedy under this Indenture and such proceeding has been discontinued or abandoned for any reason, or has been determined adversely to the Trustee or to such Holder, then and in every such case, subject to any determination in such proceedings, the Issuer, the Trustee and the Holders shall be restored severally and respectively to their former positions hereunder and thereafter all rights and remedies of the Trustee and the Holders shall continue as though no such proceeding has been instituted.

Section 6.09 Trustee May File Proofs of Claim.

The Trustee is authorized to file such proofs of claim and other papers or documents as may be necessary or advisable in order to have the claims of the Trustee (including any claim for the reasonable compensation, expenses, disbursements and advances of the Trustee, its agents and counsel) and the Holders allowed in any judicial proceedings relative to the Issuer (or any other obligor upon the Notes), its creditors or its property and shall be entitled and empowered to collect, receive and distribute any money or other property payable or deliverable on any such claims and any custodian in any such judicial proceeding is hereby authorized by each Holder to make such payments to the Trustee, and in the event that the Trustee shall consent to the making of such payments directly to the Holders, to pay to the Trustee any amount due to it for the reasonable compensation, expenses, disbursements and advances of the Trustee, the Agents and their respective agents and counsel, and any other amounts due the Trustee under Section 7.06 hereof. To the extent that the payment of any such compensation, expenses, disbursements and advances of the Trustee, the Agents and their respective agents and counsel, and any other amounts due the Trustee under Section 7.06 hereof out of the estate in any such proceeding, shall be denied for any reason, payment of the same shall be secured by a Lien on, and shall be paid out of, any and all distributions, dividends, money, securities and other properties that the Holders may be entitled to receive in such proceeding whether in liquidation or under any plan of reorganization or arrangement or otherwise. Nothing herein contained shall be deemed to authorize the Trustee to authorize or consent to or accept or adopt on behalf of any Holder any plan of reorganization, arrangement, adjustment or composition affecting the Notes or the rights of any Holder, or to authorize the Trustee to vote in respect of the claim of any Holder in any such proceeding.

Section 6.10 Priorities.

Subject to any First Lien Intercreditor Agreement, if the Trustee collects any money or property pursuant to this Article 6 or pursuant to the Security Documents, it shall pay out the money or property in the following order:

First: to the Trustee and to the Collateral Agent, in each case, and their respective agents and attorneys for amounts due under Section 7.06 hereof, including payment of all compensation, expenses and liabilities incurred, and all advances made, by the Trustee and the Collateral Agent and the costs and expenses of collection;

 

121


Second: to Holders for amounts due and unpaid on the Notes for principal, premium, if any, and interest, if any, ratably, without preference or priority of any kind, according to the amounts due and payable on the Notes for principal, premium, if any, and interest, if any, respectively; and

Third: to the Issuer or to such party as a court of competent jurisdiction shall direct, including a Guarantor, if applicable

The Trustee may fix a record date and payment date for any payment to Holders of Notes pursuant to this Section 6.10.

Section 6.11 Undertaking for Costs.

In any suit for the enforcement of any right or remedy under this Indenture or in any suit against the Trustee for any action taken or omitted by it as a Trustee, a court in its discretion may require the filing by any party litigant in the suit of an undertaking to pay the costs of the suit, and the court in its discretion may assess reasonable costs, including reasonable attorneys’ fees, against any party litigant in the suit, having due regard to the merits and good faith of the claims or defenses made by the party litigant. This Section 6.11 does not apply to a suit by the Trustee, a suit by a Holder pursuant to Section 6.07 hereof, or a suit by Holders of more than 10% in aggregate principal amount of the then outstanding Notes.

ARTICLE 7

TRUSTEE

Section 7.01 Duties of Trustee.

(a) If an Event of Default has occurred and is continuing, the Trustee will exercise such of the rights and powers vested in it by this Indenture, and use the same degree of care and skill in its exercise, as a prudent person would exercise or use under the circumstances in the conduct of such person’s own affairs.

(b) Except during the continuance of an Event of Default:

(1) the duties of the Trustee will be determined solely by the express provisions of this Indenture and the Trustee need perform only those duties that are specifically set forth in this Indenture and no others, and no implied covenants or obligations shall be read into this Indenture against the Trustee; and

(2) in the absence of bad faith on its part, the Trustee may conclusively rely, as to the truth of the statements and the correctness of the opinions expressed therein, upon certificates or opinions furnished to the Trustee and conforming to the requirements of this Indenture. However, the Trustee will examine the certificates and opinions to determine whether or not they conform to the requirements of this Indenture (but need not confirm or investigate the accuracy of mathematical calculations or other facts stated therein).

 

122


(c) The Trustee may not be relieved from liabilities for its own negligent action, its own negligent failure to act, or its own willful misconduct, except that:

(1) this paragraph does not limit the effect of paragraph (b) of this Section 7.01;

(2) the Trustee will not be liable for any error of judgment made in good faith by a Responsible Officer, unless it is proved that the Trustee was negligent in ascertaining the pertinent facts; and

(3) the Trustee will not be liable with respect to any action it takes or omits to take in good faith in accordance with a direction received by it pursuant to Section 6.05 hereof.

(d) Whether or not therein expressly so provided, every provision of this Indenture that in any way relates to the Trustee is subject to this Section 7.01.

(e) No provision of this Indenture will require the Trustee to expend or risk its own funds or incur any liability. The Trustee will be under no obligation to exercise any of its rights or powers under this Indenture at the request of any Holders, unless such Holder has offered to the Trustee security and indemnity satisfactory to it against any loss, liability or expense.

(f) The Trustee will not be liable for interest on any money received by it except as the Trustee may agree in writing with the Issuer. Money held in trust by the Trustee need not be segregated from other funds except to the extent required by law.

Section 7.02 Rights of Trustee.

(a) The Trustee may conclusively rely upon any document believed by it to be genuine and to have been signed or presented by the proper Person. The Trustee need not investigate any fact or matter stated in the document.

(b) Before the Trustee acts or refrains from acting, it may require an Officer’s Certificate or an Opinion of Counsel or both. The Trustee will not be liable for any action it takes or omits to take in good faith in reliance on such Officer’s Certificate or Opinion of Counsel. The Trustee may consult with counsel and the written advice of such counsel or any Opinion of Counsel will be full and complete authorization and protection from liability in respect of any action taken, suffered or omitted by it hereunder in good faith and in reliance thereon.

(c) The Trustee may act through its attorneys and agents and will not be responsible for the misconduct or negligence of any agent appointed with due care.

(d) The Trustee will not be liable for any action it takes or omits to take in good faith that it believes to be authorized or within the rights or powers conferred upon it by this Indenture.

(e) Unless otherwise specifically provided in this Indenture, any demand, request, direction or notice from the Issuer will be sufficient if signed by an Officer of the Issuer.

(f) The Trustee will be under no obligation to exercise any of the rights or powers vested in it by this Indenture at the request or direction of any of the Holders unless such Holders have offered to the Trustee indemnity and/or security satisfactory to the Trustee against the losses, liabilities and expenses that might be incurred by it in compliance with such request or direction.

 

123


(g) The Trustee shall not be deemed to have notice of any Default hereunder or Event of Default unless a Responsible Officer of the Trustee has actual knowledge thereof with respect to a Default or Event of Default described in Sections 6.01(a) and (b) or otherwise unless written notice of any event which is in fact such a Default or Event of Default is received by a Responsible Officer at the Corporate Trust Office of the Trustee, and such notice references the Notes and this Indenture.

(h) The rights, privileges, protections, immunities and benefits given to the Trustee, including, without limitation, its right to be indemnified, are extended to, and shall be enforceable by, the Trustee in each of its capacities hereunder.

(i) In no event shall the Trustee be responsible or liable for special, punitive, indirect, or consequential loss or damage of any kind whatsoever (including, but not limited to, loss of profit) irrespective of whether the Trustee has been advised of the likelihood of such loss or damage and regardless of the form of action.

(j) The Trustee may request that the Issuer deliver an Officer’s Certificate setting forth the names of individuals and/or titles of officers authorized at such time to take specified actions pursuant to this Indenture, which Officer’s Certificate may be signed by any person authorized to sign an Officer’s Certificate, including any person specified as so authorized in any such certificate previously delivered and not superseded.

(k) In no event shall the Trustee be responsible or liable for any failure or delay in the performance of its obligations hereunder arising out of or caused by, directly or indirectly, forces beyond its control, including, without limitation, strikes, work stoppages, epidemics or pandemics, accidents, acts of war or terrorism, civil or military disturbances, nuclear or natural catastrophes or acts of God, and interruptions, loss or malfunctions of utilities, communications or computer (software and hardware) services; it being understood that the Trustee shall use reasonable efforts which are consistent with accepted practices in the banking industry to resume performance as soon as practicable under the circumstances.

(l) The parties hereto acknowledge that in accordance with Section 326 of the U.S.A. PATRIOT Act, the Trustee, like all financial institutions and in order to help fight the funding of terrorism and money laundering, is required to obtain, verify, and record information that identifies each person or legal entity that establishes a relationship or opens an account with the Trustee. The parties to this Indenture agree that they will provide the Trustee with such information as it may request in order for the Trustee to satisfy the requirements of the U.S.A. PATRIOT Act.

(m) The Trustee shall have the right to accept and act upon instructions, including funds transfer instructions (“Instructions”) given pursuant to this Indenture and any other Transaction Document and delivered using Electronic Means; provided, however, that the Issuer and the Guarantors shall provide to the Trustee an incumbency certificate listing officers with the authority to provide such Instructions (“Instructing Officers”) and containing specimen signatures of such Instructing Officers, which incumbency certificate shall be amended by the Issuer and/or the Guarantors, as applicable, whenever a person is to be added or deleted from the listing. If the Issuer and/or the Guarantors, as applicable, elects to give the Trustee Instructions using Electronic Means and the Trustee in its discretion elects to act upon such Instructions, the Trustee’s

 

124


understanding of such Instructions shall be deemed controlling. The Issuer and the Guarantors understand and agree that the Trustee cannot determine the identity of the actual sender of such Instructions and that the Trustee shall conclusively presume that directions that purport to have been sent by an Instructing Officer listed on the incumbency certificate provided to the Trustee have been sent by such Instructing Officer. The Issuer and the Guarantors shall be responsible for ensuring that only Instructing Officers transmit such Instructions to the Trustee and that the Issuer, the Guarantors and all Instructing Officers are solely responsible to safeguard the use and confidentiality of applicable user and authorization codes, passwords and/or authentication keys upon receipt by the Issuer and/or the Guarantors, as applicable. The Trustee shall not be liable for any losses, costs or expenses arising directly or indirectly from the Trustee’s reliance upon and compliance with such Instructions notwithstanding such directions conflict or are inconsistent with a subsequent written instruction. The Issuer and the Guarantors agree: (i) to assume all risks arising out of the use of Electronic Means to submit Instructions to the Trustee, including without limitation the risk of the Trustee acting on unauthorized Instructions, and the risk of interception and misuse by third parties; (ii) that it is fully informed of the protections and risks associated with the various methods of transmitting Instructions to the Trustee and that there may be more secure methods of transmitting Instructions than the method(s) selected by the Issuer and/or the Guarantors, as applicable; (iii) that the security procedures (if any) to be followed in connection with its transmission of Instructions provide to it a commercially reasonable degree of protection in light of its particular needs and circumstances; and (iv) to notify the Trustee immediately upon learning of any compromise or unauthorized use of the security procedures.

Section 7.03 Individual Rights of Trustee.

The Trustee in its individual or any other capacity may become the owner or pledgee of Notes and may otherwise deal with the Issuer or any Affiliate of the Issuer with the same rights it would have if it were not Trustee. However, in the event that the Trustee acquires any conflicting interest it must eliminate such conflict within 90 days or resign. Any Agent may do the same with like rights and duties. The Trustee is also subject to Section 7.09 hereof

Section 7.04 Trustees Disclaimer.

The Trustee will not be responsible for and makes no representation as to the validity or adequacy of this Indenture or the Notes, it shall not be accountable for the Issuer’s use of the proceeds from the Notes or any money paid to the Issuer or upon the Issuer’s direction under any provision of this Indenture, it will not be responsible for the use or application of any money received by any Paying Agent other than the Trustee, and it will not be responsible for any statement or recital herein or any statement in the Notes or any other document in connection with the sale of the Notes or pursuant to this Indenture other than its certificate of authentication.

Section 7.05 Notice of Defaults.

If a Default or Event of Default occurs and is continuing and if it is known to a Responsible Officer of the Trustee as described in Section 7.02(g), the Trustee will deliver (or, in the case of Global Notes, transmit pursuant to the Applicable Procedures) to Holders of Notes a notice of the Default or Event of Default within 90 days after it occurs, unless such Default shall have been cured or waived, or if discovered after 90 days, promptly thereafter. Except in the case of a Default or Event of Default in payment of principal of, premium on, if any, interest, if any, on, any Note, the Trustee may withhold the notice if and so long as a committee of its Responsible Officers in good faith determines that withholding the notice is in the interests of the Holders.

 

125


Section 7.06 Compensation and Indemnity.

(a) The Issuer will pay to the Trustee from time to time reasonable compensation for its acceptance of this Indenture and services hereunder as agreed in writing between the Issuer and the Trustee. The Trustee’s compensation will not be limited by any law on compensation of a trustee of an express trust. The Issuer will reimburse the Trustee promptly upon request for all reasonable disbursements, advances and expenses incurred or made by it in addition to the compensation for its services. Such expenses will include the reasonable compensation, disbursements and expenses of the Trustee’s agents and counsel.

(b) The Issuer and the Guarantors will, jointly and severally, indemnify the Trustee against any and all losses, liabilities or expenses incurred by it arising out of or in connection with the acceptance or administration of its duties under this Indenture, including the costs and expenses of enforcing this Indenture against the Issuer and the Guarantors (including this Section 7.06) and defending itself against any claim (whether asserted by the Issuer, the Guarantors, any Holder or any other Person) or liability in connection with the exercise or performance of any of its powers or duties hereunder, except to the extent any such loss, liability or expense may be attributable to its own gross negligence or willful misconduct, as determined by a final, non-appealable decision of a court of competent jurisdiction. The Trustee will notify the Issuer promptly of any claim for which it may seek indemnity. Failure by the Trustee to so notify the Issuer will not relieve the Issuer or any of the Guarantors of their obligations hereunder. Neither the Issuer nor any Guarantor need pay for any settlement made without its consent, which consent will not be unreasonably withheld, conditioned or delayed.

(c) The obligations of the Issuer and the Guarantors under this Section 7.06 will survive the satisfaction and discharge of this Indenture.

(d) To secure the Issuer’s and the Guarantors’ payment obligations in this Section 7.06, the Trustee will have a Lien prior to the Notes on all money or property held or collected by the Trustee, except that held in trust to pay principal of, premium on, if any, interest, if any, on, particular Notes. Such Lien will survive the satisfaction and discharge of this Indenture.

(e) When the Trustee incurs expenses or renders services after an Event of Default specified in clause (h) or (i) of Section 6.01 hereof occurs, the expenses and the compensation for the services (including the fees and expenses of its agents and counsel) are intended to constitute expenses of administration under any Bankruptcy Law.

Section 7.07 Replacement of Trustee.

(a) A resignation or removal of the Trustee and appointment of a successor Trustee will become effective only upon the successor Trustee’s acceptance of appointment as provided in this Section 7.07.

 

126


(b) The Trustee may resign in writing at any time and be discharged from the trust hereby created by so notifying the Issuer. The Holders of a majority in aggregate principal amount of the then outstanding Notes may remove the Trustee by so notifying the Trustee and the Issuer in writing. The Issuer may remove the Trustee if:

(1) the Trustee fails to comply with Section 7.09 hereof;

(2) the Trustee is adjudged a bankrupt or an insolvent or an order for relief is entered with respect to the Trustee under any Bankruptcy Law;

(3) a custodian or public officer takes charge of the Trustee or its property; or

(4) the Trustee becomes incapable of acting.

(c) If the Trustee resigns or is removed or if a vacancy exists in the office of Trustee for any reason, the Issuer will promptly appoint a successor Trustee. Within one year after the successor Trustee takes office, the Holders of a majority in aggregate principal amount of the then outstanding Notes may appoint a successor Trustee to replace the successor Trustee appointed by the Issuer.

(d) If a successor Trustee does not take office within 60 days after the retiring Trustee resigns or is removed, the retiring Trustee, the Issuer, or the Holders of at least 10% in aggregate principal amount of the then outstanding Notes may petition any court of competent jurisdiction for the appointment of a successor Trustee.

(e) If the Trustee, after written request by any Holder who has been a Holder for at least six months, fails to comply with Section 7.09 hereof, such Holder may petition any court of competent jurisdiction for the removal of the Trustee and the appointment of a successor Trustee.

(f) A successor Trustee will deliver a written acceptance of its appointment to the retiring Trustee and to the Issuer. Thereupon, the resignation or removal of the retiring Trustee will become effective, and the successor Trustee will have all the rights, powers and duties of the Trustee under this Indenture. The successor Trustee will mail a notice of its succession to Holders. The retiring Trustee will promptly transfer all property held by it as Trustee to the successor Trustee; provided all sums owing to the Trustee hereunder have been paid and subject to the Lien provided for in Section 7.06 hereof Notwithstanding replacement of the Trustee pursuant to this Section 7.07, the Issuer’s obligations under Section 7.06 hereof will continue for the benefit of the retiring Trustee.

Section 7.08 Successor Trustee by Merger, etc.

If the Trustee consolidates, merges or converts into, or transfers all or substantially all of its corporate trust business to, another corporation, the successor corporation without any further act will be the successor Trustee.

 

127


Section 7.09 Eligibility; Disqualification.

There will at all times be a Trustee hereunder that is a corporation organized and doing business under the laws of the United States of America or of any state thereof that is authorized under such laws to exercise corporate trust powers, that is subject to supervision or examination by federal or state authorities and that has a combined capital and surplus of at least $100.0 million as set forth in its most recent published annual report of condition.

Section 7.10 Security Documents.

By their acceptance of the Notes, the Holders hereby authorize and direct the Trustee and the Collateral Agent to execute and deliver this Indenture, the Security Documents in which the Trustee or the Collateral Agent is named as a party, including any Security Documents executed on or after the Issue Date. It is hereby expressly acknowledged and agreed that, in doing so, the Trustee and the Collateral Agent are not responsible for the terms or contents of such agreements, or for the validity or enforceability thereof, or the sufficiency thereof for any purpose. Whether or not so expressly stated therein, in entering into, or taking (or forbearing from) any action under, this Indenture, the Security Documents, the Trustee and the Collateral Agent each shall have all of the rights, privileges, benefits, immunities, indemnities and other protections granted to it under this Indenture (in the case of the Trustee) and the Collateral Agency Agreement (in the case of the Collateral Agent) (in addition to those that may be granted to it under the terms of such other agreement or agreements).

ARTICLE 8

LEGAL DEFEASANCE AND COVENANT DEFEASANCE

Section 8.01 Option to Effect Legal Defeasance or Covenant Defeasance.

The Issuer may, at the option of its Board of Directors evidenced by a resolution set forth in an Officer’s Certificate, at any time, elect to have either Section 8.02 or 8.03 hereof be applied to all outstanding Notes upon compliance with the conditions set forth below in this Article 8.

Section 8.02 Legal Defeasance and Discharge.

Upon the Issuer’s exercise under Section 8.01 hereof of the option applicable to this Section 8.02, the Issuer and each of the Guarantors will, subject to the satisfaction of the conditions set forth in Section 8.04 hereof, be deemed to have been discharged from their obligations with respect to all outstanding Notes (including any Guarantees of such Notes) on the date the conditions set forth below are satisfied (hereinafter, “Legal Defeasance”). For this purpose, Legal Defeasance means that the Issuer and the Guarantors will be deemed to have paid and discharged the entire Indebtedness represented by the outstanding Notes (including any Guarantees of such Notes and the Security Documents with respect to such Notes and all Defaults and Events of Default cured), which will thereafter be deemed to be “outstanding” only for the purposes of Section 8.05 hereof and the other Sections of this Indenture referred to in clauses (a) and (b) below, and to have satisfied all their other obligations under such Notes, any Guarantees of such Notes the applicable Security Documents and this Indenture (and the Trustee, on demand of and at the expense of the Issuer, shall execute proper instruments acknowledging the same) and to have cured

 

128


all then existing Defaults and Events of Default, except for the following provisions which will survive until otherwise terminated or discharged hereunder:

(a) the rights of Holders of outstanding Notes to receive payments in respect of the principal of, premium on, if any, or interest, if any, on such Notes when such payments are due from the trust created pursuant to this Indenture referred to in Section 8.04 hereof;

(b) the Issuer’s obligations with respect to the Notes under Article 2 and Section 4.02 hereof;

(c) the rights, powers, trusts, duties and immunities of the Trustee hereunder and the

Issuer’s and the Guarantors’ obligations in connection therewith; and

(d) this Article 8.

Subject to compliance with this Article 8, the Issuer may exercise its option under this Section 8.02 notwithstanding the prior exercise of its option under Section 8.03 hereof.

Section 8.03 Covenant Defeasance.

Upon the Issuer’s exercise under Section 8.01 hereof of the option applicable to this Section 8.03 with respect to the Notes, the Issuer and each of the Guarantors will, subject to the satisfaction of the conditions set forth in Section 8.04 hereof, be released from each of their obligations under the covenants contained in Sections 3.09, 4.03, 4.04, 4.07, 4.08, 4.09, 4.10, 4.11, 4.12, 4.13, 4.15, 4.16 and 4.17 and clause (4) of Section 5.01 hereof with respect to the outstanding Notes on and after the date the conditions set forth in Section 8.04 hereof are satisfied (hereinafter, “Covenant Defeasance”), and the Notes will thereafter be deemed not “outstanding” for the purposes of any direction, waiver, consent or declaration or act of Holders (and the consequences of any thereof) in connection with such covenants, but will continue to be deemed “outstanding” for all other purposes hereunder (it being understood that such Notes will not be deemed outstanding for accounting purposes). For this purpose, Covenant Defeasance means that, with respect to the outstanding Notes and any Guarantees of such Notes, the Issuer and the Guarantors may omit to comply with and will have no liability in respect of any term, condition or limitation set forth in any such covenant, whether directly or indirectly, by reason of any reference elsewhere herein to any such covenant or by reason of any reference in any such covenant to any other provision herein or in any other document and such omission to comply will not constitute a Default or an Event of Default under Section 6.01 hereof, but, except as specified above, the remainder of this Indenture and such Notes and any Guarantees of such Notes will be unaffected thereby. In addition, upon the Issuer’s exercise under Section 8.01 hereof of the option applicable to this Section 8.03, subject to the satisfaction of the conditions set forth in Section 8.04 hereof, Sections 6.01(c), (d), (e), (f), (g) and (j) hereof will not constitute Events of Default.

Section 8.04 Conditions to Legal or Covenant Defeasance.

In order to exercise either Legal Defeasance or Covenant Defeasance under either Section 8.02 or 8.03 hereof:

 

129


(a) the Issuer must irrevocably deposit with the Trustee, in trust, for the benefit of the Holders of the Notes, cash in U.S. dollars, non-callable Government Securities, or a combination thereof, in such amounts as will be sufficient, without consideration of any reinvestment of interest, in the opinion of a nationally recognized investment bank, appraisal firm, or firm of independent public accountants, to pay the principal of, or interest and premium, if any, on the outstanding Notes on the Stated Maturity or on the applicable redemption date, as the case may be, and the Issuer must specify whether the Notes are being defeased to such Stated Maturity or to a particular redemption date;

(b) in the case of an election under Section 8.02 hereof, the Issuer shall deliver to the Trustee an Opinion of Counsel confirming that:

(1) the Issuer has received from, or there has been published by, the Internal Revenue Service a ruling; or

(2) since the Issue Date, there has been a change in the applicable federal income tax law,

in either case to the effect that, and based thereon such Opinion of Counsel shall confirm that, subject to customary assumptions and exclusions, the Holders of the outstanding Notes will not recognize income, gain or loss for federal income tax purposes as a result of such Legal Defeasance and will be subject to federal income tax on the same amounts, in the same manner and at the same times as would have been the case if such Legal Defeasance had not occurred;

(c) in the case of an election under Section 8.03 hereof, the Issuer shall deliver to the Trustee an Opinion of Counsel confirming that, subject to customary assumptions and exclusions, the Holders of the outstanding Notes will not recognize income, gain or loss for federal income tax purposes as a result of such Covenant Defeasance and will be subject to federal income tax on the same amounts, in the same manner and at the same times as would have been the case if such Covenant Defeasance had not occurred;

(d) no Event of Default with respect to the Notes shall have occurred and is continuing on the date of such deposit (other than an Event of Default resulting from the borrowing of funds to be applied to such deposit (and any similar and simultaneous deposit relating to other Indebtedness), and, in each case, the granting of Liens to secure such borrowings);

(e) such Legal Defeasance or Covenant Defeasance will not result in a breach or violation of, or constitute a default under, any material agreement or instrument (other than this Indenture and the agreements governing any other Indebtedness being defeased, discharged or replaced) to which the Issuer or any of its Subsidiaries is a party or by which the Issuer or any of its Subsidiaries is bound (other than an Event of Default resulting from the borrowing of funds to be applied to such deposit (and any similar and simultaneous deposit relating to other Indebtedness), and, in each case, the granting of Liens to secure such borrowings);

 

130


(f) the Issuer must deliver to the Trustee an Officer’s Certificate stating that the deposit was not made by the Issuer with the intent of preferring the Holders of the Notes over the other creditors of the Issuer with the intent of defeating, hindering, delaying or defrauding any creditors of the Issuer or others; and

(g) the Issuer must deliver to the Trustee an Officer’s Certificate and an Opinion of Counsel, which Opinion of Counsel may be subject to customary assumptions and exclusions, each stating that all conditions precedent relating to the Legal Defeasance or the Covenant Defeasance have been complied with.

Section 8.05 Deposited Money and Government Securities to be Held in Trust; Other Miscellaneous Provisions.

Subject to Section 8.06 hereof, all money and non-callable Government Securities (including the proceeds thereof) deposited with the Trustee (or other qualifying trustee, collectively for purposes of this Section 8.05, the “Trustee”) pursuant to Section 8.04 hereof in respect of the outstanding Notes will be held in trust and applied by the Trustee, in accordance with the provisions of such Notes and this Indenture, to the payment, either directly or through any Paying Agent (including the Issuer acting as Paying Agent) as the Trustee may determine, to the Holders of all sums due and to become due thereon in respect of principal, premium, if any, and interest, if any, but such money need not be segregated from other funds except to the extent required by law.

The Issuer will pay and indemnify the Trustee against any tax, fee or other charge imposed on or assessed against the cash or non-callable Government Securities deposited pursuant to Section 8.04 hereof or the principal and interest received in respect thereof other than any such tax, fee or other charge which by law is for the account of the Holders of the outstanding Notes.

Notwithstanding anything in this Article 8 to the contrary, the Trustee will deliver or pay to the Issuer from time to time upon the request of the Issuer any money or non-callable Government Securities held by it as provided in Section 8.04 hereof which, in the opinion of a nationally recognized firm of independent public accountants expressed in a written certification thereof delivered to the Trustee (which may be the opinion delivered under Section 8.04(a) hereof), are in excess of the amount thereof that would then be required to be deposited to effect an equivalent Legal Defeasance or Covenant Defeasance.

Section 8.06 Repayment to Issuer.

Any money deposited with the Trustee or any Paying Agent, or then held by the Issuer, in trust for the payment of the principal of, premium on, if any, or interest, if any, on any Note and remaining unclaimed for two years after such principal, premium, if any, or interest, if any, has become due and payable shall be paid to the Issuer on its request or (if then held by the Issuer) will be discharged from such trust; and the Holder of such Note will thereafter be permitted to look only to the Issuer for payment thereof, and all liability of the Trustee or such Paying Agent with respect to such trust money, and all liability of the Issuer as trustee thereof, will thereupon cease; provided, however, that the Trustee or such Paying Agent, before being required to make any such repayment, may at the expense of the Issuer cause to be published once, in the New York Times and The Wall Street Journal (national edition), notice that such money remains unclaimed and that, after a date specified therein, which will not be less than 30 days from the date of such notification or publication, any unclaimed balance of such money then remaining will be repaid to the Issuer.

 

131


Section 8.07 Reinstatement.

If the Trustee or Paying Agent is unable to apply any U.S. dollars or non-callable Government Securities in accordance with Section 8.02 or 8.03 hereof, as the case may be, by reason of any order or judgment of any court or Governmental Authority enjoining, restraining or otherwise prohibiting such application, then the Issuer’s and the Guarantors’ obligations under this Indenture and the Notes and any Guarantees of such Notes will be revived and reinstated as though no deposit had occurred pursuant to Section 8.02 or 8.03 hereof until such time as the Trustee or Paying Agent is permitted to apply all such money in accordance with Section 8.02 or 8.03 hereof, as the case may be; provided, however, that, if the Issuer makes any payment of principal of, premium on, if any, interest, if any, on, any Note following the reinstatement of its obligations, the Issuer will be subrogated to the rights of the Holders of such Notes to receive such payment from the money held by the Trustee or Paying Agent.

ARTICLE 9

AMENDMENT, SUPPLEMENT AND WAIVER

Section 9.01 Without Consent of Holders of Notes.

Notwithstanding Section 9.02 of this Indenture, without the consent of any Holder, the Issuer, the Guarantors, the Trustee and the Collateral Agent may amend or supplement this Indenture, the Notes, any Guarantee or any Security Document:

(a) to cure any ambiguity, mistake defect or inconsistency;

(b) to provide for uncertificated Notes in addition to or in place of certificated Notes;

(c) to provide for the assumption of the Issuer’s obligations to holders of Notes in the case of a merger or consolidation or sale of all or substantially all of the Issuer’s assets;

(d) to make any change that would provide any additional rights or benefits to the Holders or that does not adversely affect in any material respect the legal rights hereunder of any Holder;

(e) to comply with requirements of the Commission in connection with the qualification of this Indenture under the TIA to the extent this Indenture is to be so qualified;

(f) to add or modify covenants for the benefit of the Holders or to surrender any right or power conferred upon the Issuer or any Guarantor;

(g) to add a co-issuer or a Guarantor under this Indenture;

(h) to comply with the rules of any applicable securities depositary;

 

132


(i) to conform the text of this Indenture, the Notes, any Guarantee or any Security Document to any provision of the “Description of Notes” section of the Offering Memorandum, as set forth in an Officer’s Certificate to that effect;

(j) to evidence and provide for the acceptance and appointment under this Indenture or any Security Document of a successor Trustee, Collateral Agent or paying agent pursuant to the requirements hereof or thereof;

(k) to provide for or confirm the issuance of Additional Notes in accordance with this Indenture;

(l) to provide for any Guarantee with respect to the Notes or to effect the release of a Guarantor from any of its obligations under its Guarantee, this Indenture or the Security Documents to the extent permitted hereby or thereby;

(m) to provide for the issuance of exchange notes;

(n) to add customary provisions allowing for the issuance of new notes into escrow;

(o) to enter into any Applicable Intercreditor Agreement;

(p) to confirm or complete the grant of, secure, or expand the Collateral securing, or to add additional assets as Collateral to secure, the Notes and Guarantees;

(q) to confirm and evidence the release, termination or discharge of any Lien or security interest on the Collateral securing the Notes when permitted or required by this Indenture, or the Security Documents;

(r) in the case of any Security Document, to include therein any legend required to be set forth therein pursuant to any Applicable Intercreditor Agreements or to modify any such legend as required by any Applicable Intercreditor Agreements;

(s) to provide for the succession of any parties to the Security Documents (and other amendments that are administrative or ministerial in nature);

(t) in the case of the Collateral Agency Agreement, in order to subject the security interests in the Collateral in respect of any Additional First Lien Obligations to the terms of the Collateral Agency Agreement, in each case to the extent the incurrence of such Indebtedness, and the grant of all Liens on the Collateral held for the benefit of such Indebtedness were not prohibited under this Indenture; or

(u) with respect to any Security Document, to the extent such amendment is reasonably necessary to comply with the terms of the Collateral Agency Agreement.

Upon the request of the Issuer, and upon receipt by the Trustee and the Collateral Agent of the documents described in Sections 7.02 and 9.05 hereof (as applicable), the Trustee and the Collateral Agent will join with the Issuer (and, with respect to an amended or supplemental indenture for the addition of a new Guarantor pursuant to this Indenture, such new Guarantor) in

 

133


the execution of any amended or supplemental indenture authorized or permitted by the terms of this Indenture and to make any further appropriate agreements and stipulations that may be therein contained, but neither the Trustee nor the Collateral Agent will be obligated to enter into such amended or supplemental indenture that affects its own rights, duties or immunities under this Indenture or otherwise.

Section 9.02 With Consent of Holders of Notes.

Except as provided below in this Section 9.02, the Issuer, the Guarantors, the Trustee and the Collateral Agent may amend or supplement this Indenture (including, without limitation, Section 3.09, 4.10 and 4.15 hereof) and the Notes, any Guarantee or the Security Documents with the consent of the Holders of at least a majority in aggregate principal amount of the then outstanding Notes (including, without limitation, Additional Notes, if any) voting as a single class (including, without limitation, consents obtained in connection with a tender offer or exchange offer for, or purchase of, any Notes), and, subject to Sections 6.04 and 6.07 hereof, any existing Default (other than a Default on the payment of the principal of, premium on, if any, or interest, if any, on, the Notes, except a payment default resulting from an acceleration that has been rescinded) or compliance with any provision of this Indenture, the Notes, any Guarantees, the Security Documents or any Applicable Intercreditor Agreement may be waived with the consent of the Holders of a majority in aggregate principal amount of the then outstanding Notes (including, without limitation, Additional Notes, if any) voting as a single class (including, without limitation, consents obtained in connection with a tender offer or exchange offer for, or purchase of, any Notes). Section 2.08 hereof shall determine which Notes are considered to be “outstanding” for purposes of this Section 9.02.

Upon the request of the Issuer accompanied by a resolution of its Board of Directors authorizing the execution of any such amended or supplemental indenture, and upon the filing with the Trustee and the Collateral Agent of evidence satisfactory to each of the Trustee and the Collateral Agent of the consent of the Holders of Notes as aforesaid, and upon receipt by the Trustee and the Collateral Agent of the documents described in Sections 7.02 and 9.05 hereof (as applicable), the Trustee and the Collateral Agent will join with the Issuer and solely to the extent applicable, the Guarantors, in the execution of such amended or supplemental indenture unless such amended or supplemental indenture directly affects the Trustee’s or the Collateral Agent’s own rights, duties or immunities under this Indenture or otherwise, in which case the Trustee or the Collateral Agent may in its discretion, but will not be obligated to, enter into such amended or supplemental Indenture.

It is not necessary for the consent of the Holders of Notes under this Section 9.02 to approve the particular form of any proposed amendment, supplement or waiver, but it is sufficient if such consent approves the substance thereof.

After an amendment, supplement or waiver under this Section 9.02 becomes effective, the Issuer will transmit in accordance with the Applicable Procedures to the Holders of Notes affected thereby a notice briefly describing the amendment, supplement or waiver. Any failure of the Issuer to mail or transmit such notice, or any defect therein, will not, however, in any way impair or affect the validity of any such amended or supplemental indenture or waiver. Subject to Section 6.04 hereof, the Holders of a majority in aggregate principal amount of the Notes then outstanding

 

134


voting as a single class may waive compliance in a particular instance by the Issuer with any provision of this Indenture, the Notes, the Guarantees or the Security Documents with respect to the Notes. However, without the consent of each affected Holder, an amendment, supplement or waiver under this Section 9.02 may not (with respect to any Notes held by a non-consenting Holder):

(a) reduce the principal amount of Notes whose Holders must consent to an amendment, supplement or waiver;

(b) reduce the principal of or change the stated final maturity of any such Note or alter or waive the provisions with respect to the redemption of such Notes (other than provisions relating to (a) notice periods for redemption and conditions to redemption and (b) as provided above with respect to Sections 3.09, 4.10 and 4.15 hereof);

(c) reduce the rate of or change the time for payment of interest on any such Note;

(d) waive a Default or Event of Default in the payment of principal of, premium on, if any, or interest, if any, on, such Notes (except a rescission of acceleration of such Notes by the Holders of at least a majority in aggregate principal amount of the then outstanding Notes and a waiver of the payment default that resulted from such acceleration);

(e) make any such Note payable in currency other than that stated in such Notes;

(f) make any change in the provisions of this Indenture relating to waivers of past Defaults or the rights of Holders of such Notes to receive payments of principal of, premium, if any, on, or interest, if any, on such Notes; or

(g) make any change in the preceding amendment and waiver provisions.

Furthermore, without the consent of the Holders of at least two-thirds in aggregate principal amount of the Notes then outstanding voting as one class, an amendment or waiver may not (A) make any change in any Security Document or the provisions in this Indenture relating to the Collateral or the Security Documents or the application of trust proceeds of the Collateral in any case that would release all or substantially all of the Collateral from the Liens of the Security Documents, or (B) change or alter the priority of the Liens securing Obligations in respect of the Notes in any way materially adverse, taken as a whole, to the holders of the Notes, in each case except as permitted by the terms of this Indenture or the Security Documents.

For the avoidance of doubt, no amendment to, or deletion of any of the covenants set forth in Article 4 or action taken in compliance with the covenants in effect at the time of such action, shall be deemed to impair or affect any legal rights of any Holders to receive payment of principal of or premium, if any, or interest on the Notes or to institute suit for the enforcement of any payment on or with respect to such Holder’s Notes.

 

135


Section 9.03 Revocation and Effect of Consents.

Until an amendment, supplement or waiver becomes effective, a consent to it by a Holder is a continuing consent by the Holder and every subsequent Holder of a Note or portion of a Note that evidences the same debt as the consenting Holder’s Note, even if notation of the consent is not made on any Note. However, any such Holder or subsequent Holder may revoke the consent as to its Note if the Trustee receives written notice of revocation before the date the amendment, supplement or waiver becomes effective. An amendment, supplement or waiver becomes effective in accordance with its terms and thereafter binds every Holder.

Section 9.04 Notation on or Exchange of Notes.

The Trustee may place an appropriate notation about an amendment, supplement or waiver on any Note thereafter authenticated. The Issuer in exchange for all Notes may issue and the Trustee shall, upon receipt of an Authentication Order, authenticate new Notes that reflect the amendment, supplement or waiver.

Failure to make the appropriate notation or issue a new Note will not affect the validity and effect of such amendment, supplement or waiver.

Section 9.05 Trustee to Sign Amendments, etc.

The Trustee and the Collateral Agent shall sign any amendment, supplement or waiver authorized pursuant to this Article 9 if the amendment, supplement or wavier does not adversely affect the rights, duties, liabilities or immunities of the Trustee or the Collateral Agent, as applicable. The Issuer may not sign an amendment, supplement or waiver until the Board of Directors of the Issuer approves it. In executing any amendment, supplement or waiver, the Trustee and the Collateral Agent shall be provided with and (subject to Section 7.01 hereof) shall be fully protected in relying upon, in addition to the documents required by Section 12.02 hereof, an Officer’s Certificate and an Opinion of Counsel each stating that the execution of such amended or supplemental indenture or security documents or intercreditor agreements, or waiver, is authorized or permitted by this Indenture.

ARTICLE 10

GUARANTEES

Section 10.01 Guarantee.

(a) Subject to this Article 10, each of the Guarantors hereby, jointly and severally, unconditionally guarantees to each Holder and to the Trustee and its successors and assigns, irrespective of the validity and enforceability of this Indenture, the Notes or the obligations of the Issuer hereunder or thereunder, that:

(1) the principal of, premium, if any, on, and interest, if any, on the Notes will be promptly paid in full when due, whether at maturity, by acceleration, redemption or otherwise, and interest on the overdue principal of, premium on, if any, interest, if any, on, the Notes, if lawful, and all other obligations of the Issuer to the Holders or the Trustee hereunder or thereunder will be promptly paid in full or performed, all in accordance with the terms hereof and thereof; and

 

136


(2) in case of any extension of time of payment or renewal of any Notes or any of such other obligations, that same will be promptly paid in full when due or performed in accordance with the terms of the extension or renewal, whether at stated maturity, by acceleration or otherwise.

Failing payment when due of any amount so guaranteed or any performance so guaranteed for whatever reason, the Guarantors will be jointly and severally obligated to pay the same immediately. Each Guarantor agrees that this is a guarantee of payment and not a guarantee of collection.

(b) The Guarantors hereby agree that their obligations hereunder are unconditional, irrespective of the validity, regularity or enforceability of the Notes or this Indenture, the absence of any action to enforce the same, any waiver or consent by any Holder with respect to any provisions hereof or thereof, the recovery of any judgment against the Issuer, any action to enforce the same or any other circumstance which might otherwise constitute a legal or equitable discharge or defense of a guarantor. Each Guarantor hereby waives diligence, presentment, demand of payment, filing of claims with a court in the event of insolvency or bankruptcy of the Issuer, any right to require a proceeding first against the Issuer, protest, notice and all demands whatsoever and covenant that this Guarantee will not be discharged except by complete performance of the obligations contained in the Notes and this Indenture.

(c) If any Holder or the Trustee is required by any court or otherwise to return to the Issuer, the Guarantors or any custodian, trustee, liquidator or other similar official acting in relation to either the Issuer or the Guarantors, any amount paid by either to the Trustee or such Holder, this Guarantee, to the extent theretofore discharged, will be reinstated in full force and effect.

(d) Each Guarantor agrees that it will not be entitled to any right of subrogation in relation to the Holders in respect of any obligations guaranteed hereby until payment in full of all obligations guaranteed hereby. Each Guarantor further agrees that, as between the Guarantors, on the one hand, and the Holders and the Trustee, on the other hand, (1) the maturity of the obligations guaranteed hereby may be accelerated as provided in Article 6 hereof for the purposes of this Guarantee, notwithstanding any stay, injunction or other prohibition preventing such acceleration in respect of the obligations guaranteed hereby, and (2) in the event of any declaration of acceleration of such obligations as provided in Article 6 hereof, such obligations (whether or not due and payable) will forthwith become due and payable by the Guarantors for the purpose of this Guarantee. The Guarantors will have the right to seek contribution from any non-paying Guarantor so long as the exercise of such right does not impair the rights of the Holders under the Guarantee.

Section 10.02 Limitation on Guarantor Liability.

Each Guarantor, and by its acceptance of Notes, each Holder, hereby confirms that it is the intention of all such parties that the Guarantee of such Guarantor not constitute a fraudulent transfer or conveyance for purposes of Bankruptcy Law, the Uniform Fraudulent Conveyance Act, the Uniform Fraudulent Transfer Act or any similar federal or state law to the extent applicable to any Guarantee. To effectuate the foregoing intention, the Trustee, the Holders and the Guarantors hereby irrevocably agree that the obligations of such Guarantor will be limited to the maximum amount that will, after giving effect to such maximum amount and all other contingent and fixed

 

137


liabilities of such Guarantor that are relevant under such laws, and after giving effect to any collections from, rights to receive contribution from or payments made by or on behalf of any other Guarantor in respect of the obligations of such other Guarantor under this Article 10, result in the obligations of such Guarantor under its Guarantee not constituting a fraudulent transfer or conveyance.

Section 10.03 Execution and Delivery of Guarantee.

To evidence its Guarantee set forth in Section 10.01 hereof, each Guarantor hereby agrees that this Indenture or, if applicable, a Supplemental Indenture substantially in the form of Exhibit E, shall be executed on behalf of such Guarantor by an Officer of such Guarantor.

If an Officer whose signature is on this Indenture no longer holds that office at the time the Trustee authenticates the Note, the Guarantee will be valid nevertheless.

The delivery of any Note by the Trustee, after the authentication thereof hereunder, will constitute due delivery of the Guarantee set forth in this Indenture on behalf of the Guarantors.

Section 10.04 Releases.

The Guarantee of a Guarantor will be released and discharged automatically and unconditionally:

(a) upon the sale, disposition, exchange or other transfer (including through merger, consolidation or otherwise) of the Capital Stock of the Guarantor, after which such Guarantor is no longer a Restricted Subsidiary, or all or substantially all of the assets of such Guarantor (other than to the Issuer or a Restricted Subsidiary) if such sale, disposition, exchange or other transfer is not prohibited by this Indenture, and the release is otherwise not prohibited by this Indenture;

(b) upon the liquidation, winding up or dissolution of such Guarantor or the merger or consolidation of such Guarantor with and into the Issuer or another Guarantor in accordance with the applicable provisions of this Indenture;

(c) following delivery at any time by the Issuer to the Trustee of an Officer’s Certificate to the effect that the aggregate amount of Indebtedness for borrowed money, Finance Lease Obligations, purchase money obligations or debt obligations evidenced by bonds, notes, debentures or similar instruments or drawn letters of credit then outstanding of such Guarantor (other than any such Indebtedness owed to the Issuer or any Guarantor) does not exceed $250.0 million (excluding the Notes, and excluding any other Indebtedness that will be released or discharged with respect to such Guarantor substantially concurrently with any release pursuant to this clause (c)); provided that such Guarantee will be reinstated if and to the extent required under Section 4.16 subsequent to such release;

(d) upon Legal Defeasance or satisfaction and discharge of the Notes as provided in Section 8.02 and Article 11;

 

138


(e) upon the occurrence of a Covenant Suspension Event, provided that if, after any Covenant Suspension Event, a Reversion Date shall occur, then the Suspension Period with respect to such Covenant Suspension Event shall terminate and all actions reasonably necessary to provide that the Notes shall have been unconditionally guaranteed by such Guarantor (if and to the extent such guarantee is required pursuant to Section 4.16) shall be taken within 90 days after such Reversion Date or as soon as reasonably practicable thereafter;

(f) upon the occurrence of any event after which such Guarantor is no longer a Restricted Subsidiary;

(g) if the Issuer designates such Guarantor as an Unrestricted Subsidiary in accordance with the applicable provisions of this Indenture; or

(h) as set forth in Article 9 or in accordance with the provisions of any Applicable Intercreditor Agreement then in effect with respect to the Notes.

The Trustee shall not be required to execute any document or give any confirmation as to or otherwise evidence any release or discharge of any Guarantee unless and until (1) requested in writing to do so by the Issuer and (2) the Issuer delivers an Officer’s Certificate and an Opinion of Counsel to the Trustee stating that all conditions precedent to the release and discharge of the Guarantee have been satisfied.

ARTICLE 11

SATISFACTION AND DISCHARGE

Section 11.01 Satisfaction and Discharge.

This Indenture will be discharged and will cease to be of further effect as to all Notes issued hereunder, when:

(a) either:

(1) all Notes that have been authenticated, except lost, stolen or destroyed Notes that have been replaced or paid and Notes for whose payment money has been deposited in trust or segregated and held in trust by the Issuer and thereafter repaid to the Issuer, have been delivered to the Trustee for cancellation; or

(2) all Notes that have not been delivered to the Trustee for cancellation have become due and payable by reason of the mailing or transmitting of a notice of redemption or otherwise or will become due and payable within one year or are to be called for redemption within one year under irrevocable arrangements for the giving of notice of redemption by the Trustee in the name, and at the expense, of the Issuer, and the Issuer or any Guarantor has irrevocably deposited or caused to be deposited with the Trustee as trust funds in trust solely for the benefit of the Holders of the Notes, cash in U.S. dollars, non-callable Government Securities, or a combination thereof, in such amounts as will be sufficient, without consideration of any reinvestment of interest, to pay and discharge the entire Indebtedness on the Notes not delivered to the Trustee for cancellation for principal, premium, if any, and interest, if any, to the date of maturity or redemption;

 

139


(b) in respect of subclause (2) of clause (a) of this Section 11.01, no Event of Default has occurred and is continuing on the date of the deposit (other than an Event of Default resulting from the borrowing of funds to be applied to such deposit and any similar and simultaneous deposit relating to other Indebtedness and, in each case, the granting of Liens to secure such borrowings) and the deposit will not result in a breach or violation of, or constitute a default under, any other instrument to which the Issuer or any Guarantor is a party or by which the Issuer or any Guarantor is bound (other than with respect to the borrowing of funds to be applied concurrently to make the deposit required to effect such satisfaction and discharge and any similar concurrent deposit relating to other Indebtedness, and in each case the granting of Liens to secure such borrowings);

(c) the Issuer or any Guarantor has paid or caused to be paid all sums payable by it under this Indenture with respect to the Notes; and

(d) the Issuer has delivered irrevocable written instructions to the Trustee under this Indenture to apply the deposited money toward the payment of the Notes at maturity or on the redemption date, as the case may be.

In addition, the Issuer must deliver an Officer’s Certificate and an Opinion of Counsel to the Trustee to the effect that all conditions precedent to satisfaction and discharge of the Notes have been complied with.

Notwithstanding the satisfaction and discharge of this Indenture, if money has been deposited with the Trustee pursuant to subclause (2) of clause (a) of this Section 11.01, the provisions of Sections 11.02 and 8.06 hereof will survive. In addition, nothing in this Section 11.01 will be deemed to discharge those provisions of Section 7.07 hereof, that, by their terms, survive the satisfaction and discharge of this Indenture.

Section 11.02 Application of Trust Money.

Subject to the provisions of Section 8.06 hereof, all money deposited with the Trustee pursuant to Section 11.01 hereof shall be held in trust and applied by it, in accordance with the provisions of the Notes and this Indenture, to the payment, either directly or through any Paying Agent (including the Issuer acting as its own Paying Agent) as the Trustee may determine, to the Persons entitled thereto, of the principal, premium, if any, interest, if any, for whose payment such money has been deposited with the Trustee; but such money need not be segregated from other funds except to the extent required by law.

If the Trustee or Paying Agent is unable to apply any money or Government Securities in accordance with Section 11.01 hereof by reason of any legal proceeding or by reason of any order or judgment of any court or Governmental Authority enjoining, restraining or otherwise prohibiting such application, the Issuer’s and any Guarantor’s obligations under this Indenture and the Notes shall be revived and reinstated as though no deposit had occurred pursuant to Section 11.01 hereof; provided that if the Issuer has made any payment of principal of, premium on, if any, or interest, if any, on, any Notes because of the reinstatement of its obligations, the Issuer shall be subrogated to the rights of the Holders of such Notes to receive such payment from the money or Government Securities held by the Trustee or Paying Agent.

 

140


ARTICLE 12

COLLATERAL AND SECURITY

Section 12.01 General.

The Notes are, and any Guarantees will be, secured on a first-priority basis (subject to permitted encumbrances) by Liens on the Collateral, other than, in each case, during any Suspension Period with respect to the Notes. The Liens securing the Notes and the Guarantees will be shared equally and ratably (subject to Liens permitted to be incurred under Section 4.12) with the holders of other First Lien Obligations.

Section 12.02 Security Documents.

(a) In order to secure the due and punctual payment of the Note Obligations, when the same shall be due and payable, whether on an Interest Payment Date, at maturity, by acceleration, repurchase, redemption or otherwise, and interest on the overdue principal of and interest (to the extent permitted by law) on the Notes and performance of all other Note Obligations, (i) the Issuer and the Guarantors, if any, have prior to the Issue Date, entered into Security Documents granting the Collateral Agent a Lien on (A) substantially all the existing and future tangible and intangible assets and rights of the Issuer and the Guarantors, if any (other than, in each case, Excluded Assets) and (B) Equity Interests in all direct Subsidiaries of the Issuer and each Guarantor, if any (other than, in each case, Excluded Capital Stock), and (ii) the Issuer agrees that it shall take all such action as shall be required to ensure that the Note Obligations will (other than, in each case, during any Suspension Period with respect to the Notes) be secured by a Lien, subject only to Permitted Liens, on the Collateral.

(b) To the extent, but only to the extent, permitted hereby, the Issuer and the Guarantors may incur Additional First Lien Obligations. Any additional class or series of Additional First Lien Obligations will be secured by Liens on the Collateral that rank pari passu with the Liens securing First Lien Obligations, in each case, under and pursuant to the Security Documents, once the Senior Class Debt Representative with respect to any such class or series of Additional First Lien Obligations, acting on behalf of the holders of such series of Additional First Lien Obligations, (1) becomes a party to the First Lien Intercreditor Agreement by satisfying the conditions set forth therein and (2) becomes a party to the Collateral Agency Agreement.

(c) If the Issuer or any of the Guarantors incurs Additional First Lien Obligations, the Collateral Agent, on behalf of itself, the other Senior Class Debt Representatives, acting on behalf of the holders of the applicable series of Additional First Lien Obligations, and the other agents (if any) will, as applicable, enter into a joinder to the First Lien Intercreditor Agreement substantially in the form of Exhibit A-1 thereto.

(d) If the Issuer or any of the Guarantors incurs Indebtedness secured by a Lien on the Collateral that is junior in priority relative to the Liens on the Collateral securing the First Lien Obligations, the Issuer, the Guarantors, the Collateral Agent, acting on behalf of itself, the Trustee, acting on behalf of the Holders of the Notes, the other collateral agents (if any) and the applicable Junior Lien Representative, on behalf of itself and the applicable Junior Lien Secured Parties, will

 

141


enter into a junior lien intercreditor agreement, substantially in the form attached hereto as Exhibit F or which otherwise constitutes a junior lien intercreditor agreement that is an Applicable Intercreditor Agreement (any such junior lien intercreditor agreement, the “Junior Lien Intercreditor Agreement”).

(e) The Note Documents (other than any Applicable Intercreditor Agreement) will be subject to the terms, limitations and conditions set forth in each Applicable Intercreditor Agreement. Each Holder of Notes, by its acceptance of a Note, is deemed to (i) have consented and agreed to the terms of each Security Document (including the First Lien Intercreditor Agreement and each other Applicable Intercreditor Agreement, if any, entered into after the Issue Date in accordance with clause (d) of this Section 12.02), as originally in effect and as amended, supplemented or replaced from time to time in accordance with its terms or the terms of this Indenture, the First Lien Intercreditor Agreement or, if applicable, each Applicable Intercreditor Agreement, (ii) have authorized and directed the Trustee to enter into or execute a joinder with respect to (A) the Collateral Agency Agreement on the Issue Date, (B) the First Lien Intercreditor Agreement on the Issue Date and (C) each other Applicable Intercreditor Agreement at any time after the Issue Date in accordance with clause (d) of this Section 12.02, (iii) have consented to the appointment of the Collateral Agent pursuant to the Collateral Agency Agreement, (iv) have authorized and directed the Collateral Agent to enter into the Security Documents to which it is, or is intended to be, a party, and (v) have authorized and empowered the Collateral Agent (through the Collateral Agency Agreement, the First Lien Intercreditor Agreement and each other Applicable Intercreditor Agreement, if any) to bind the Holders of Notes as set forth in the Security Documents to which they are a party and to perform its obligations and exercise its rights and powers thereunder, including entering into amendments permitted by the terms of the Note Documents. To the extent that any provision of the Note Documents is not consistent with or contradicts the Collateral Agency Agreement (or the First Lien Intercreditor Agreement or Applicable Intercreditor Agreements (if any)), the Collateral Agency Agreement, the First Lien Intercreditor Agreement and/or the other Applicable Intercreditor Agreements (if any) shall govern.

(f) Each Holder of Notes, by its acceptance of a Note, is deemed to have:

(1) authorized, consented to and directed the Trustee to enter into and join the Collateral Agency Agreement, including by its execution of applicable joinder documentation in its capacity as “New Senior Class Debt Representative” (as defined in the Collateral Agency Agreement) in respect of the Note Obligations;

(2) other than during any Suspension Period, agreed (in its capacity as a Holder of Notes) that it is subject to and bound by the provisions of the Collateral Agency Agreement, each Security Document, the First Lien Intercreditor Agreement and each other Applicable Intercreditor Agreement in effect at any time;

(3) ratified the Collateral Agent’s execution and delivery of the Security Documents prior to the date hereof (in accordance with the Collateral Agency Agreement);

 

142


(4) consented and agreed that the Collateral Agent may execute and deliver any additional Security Documents (including any Applicable Intercreditor Agreement) not in effect as of the date hereof and act in accordance with the terms thereof;

(5) subject to the terms of any Applicable Intercreditor Agreement, consented and agreed that the Collateral Agent may, in its sole discretion and without the consent of the Trustee or the Holders, take all actions it deems necessary or appropriate in order to:

(A) enforce any of the terms of the Security Documents; and

(B) collect and receive any and all amounts payable in respect of the Note Obligations of the Issuer and the Guarantors to the Holders, the Collateral Agent or the Trustee under the Note Documents.

Section 12.03 Recording, Registration and Opinions; Trustees Disclaimer Regarding Collateral.

(a) Unless the Collateral has been released (including during a Suspension Period), the Issuer and, if applicable, any Guarantors, shall take or cause to be taken all actions required pursuant to the terms of the Security Documents to perfect, maintain, preserve and protect the Lien on the Collateral granted by the Collateral Documents (subject only to Permitted Liens and to the terms of the Security Documents), including without limitation arranging for the filing of financing statements, continuation statements and any instruments of further assurance, in such manner and in such places as may be required by law fully to preserve and protect the rights of the Holders, the Trustee and the Collateral Agent under the Note Documents to all property now or hereafter at any time comprising the Collateral. The Issuer shall from time to time promptly pay all financing, continuation statements, registration and/or filing fees, charges and taxes relating to the Note Documents, any amendments thereto and any other instruments of further assurance required hereunder or pursuant to the Collateral Documents. Neither the Trustee nor the Collateral Agent shall have any obligation to, and neither of them shall be responsible for any failure to, so register, file or record.

(b) [Reserved.]

(c) Notwithstanding anything to the contrary set forth in the Note Documents, neither the Trustee nor the Collateral Agent shall be responsible for the existence, genuineness or value of any of the Collateral, or for the creation, validity, perfection, priority or enforceability of the Liens in any of the Collateral, whether impaired by operation of law or by reason of any action or omission to act on its part hereunder, for the validity or sufficiency of the Collateral or any agreement or assignment contained therein, for the validity of the title of the Issuer to the Collateral, for insuring the Collateral or for the payment of taxes, charges, assessments or Liens upon the Collateral or otherwise as to the maintenance of the Collateral.

(d) The Trustee shall have no duty to ascertain or inquire as to the performance or observance of any of the terms of this Indenture or any Security Document by the Issuer, any Guarantor or any other Person that is a party thereto or bound thereby. The Trustee shall not be responsible or liable for seeing to or monitoring the attachment, perfection, or priority of any lien or security interest created or intended to be created in the Collateral hereby or by any of the

 

143


Security Documents. The Trustee shall not be responsible for the preparation, correctness, filing, re-filing, recording or re-recording of any security documents or instruments, including UCC financing statements or continuation statements in any public office at any time or times or otherwise perfecting or maintaining the perfection of any lien or security interest in any of the Collateral.

Section 12.04 Possession, Use and Release of Collateral.

(a) Each Holder, by accepting a Note, consents and agrees to the provisions of the Note Documents governing the possession, use and release of Collateral. Each Holder, by accepting a Note, consents and agrees that Collateral may, and, as applicable, shall, be released or substituted in accordance with the terms of the Security Documents.

(b) The Liens on the Collateral in favor of the Collateral Agent with respect to all Note Obligations of the Issuer and the Guarantors secured by such Collateral will be released automatically and unconditionally:

(1) upon payment in full of all outstanding Notes and all other amounts due under this Indenture (including any Guarantee), the Collateral Agency Agreement and the Notes;

(2) upon legal defeasance or satisfaction and discharge of the Notes as set forth under Articles 8 and 11, respectively;

(3) as to any Collateral that constitutes all or substantially all of the Collateral, with the consent of the holders of at least two-thirds in principal amount of the Notes then outstanding;

(4) to enable the Issuer and/or any Guarantor to consummate the disposition of property or assets to a Person other than the Issuer or a Guarantor (unless such property or other assets transferred to a Person that is the Issuer or a Guarantor are automatically, substantially concurrently with or in advance of such release, the subject of Liens granted by such transferee securing the Notes) to the extent not prohibited under Section 4.10;

(5) in the case of a sale or other transfer as part of or in connection with an Asset Sale by the Issuer or any Guarantor to a Person other than the Issuer or a Guarantor (unless such property or other assets transferred to a Person that is the Issuer or a Guarantor are automatically, substantially concurrently with or in advance of such release, the subject of Liens granted by such transferee securing the Notes) in a transaction permitted hereunder;

(6) with respect to any Collateral owned by a Guarantor whose Capital Stock is sold or otherwise disposed of in accordance with the terms of this Indenture to a Person that is not (either before or after giving effect to such transaction) the Issuer or a Restricted Subsidiary, upon such sale or other disposition;

 

144


(7) upon the occurrence of a Covenant Suspension Event, provided that, if, after any Covenant Suspension Event, a Reversion Date shall occur, then the Suspension Period with respect to such Covenant Suspension Event shall terminate and the Issuer will take all actions reasonably necessary to provide that the Notes and any Guarantees shall be secured on a first-priority basis (subject to permitted encumbrances) by Liens on the Collateral within 120 days after such Reversion Date or as soon as reasonably practicable thereafter (but in each case, subject to all limitations and exclusions set forth herein and in the Security Documents);

(8) with respect to property or other assets owned by a Guarantor that is released from its Guarantee pursuant to the terms of this Indenture, concurrently upon the release from such Guarantee;

(9) with respect to property or other assets that does not constitute Collateral (or ceases to constitute Collateral) (including by being or becoming an Excluded Asset); and

(10) as required by the terms of any Applicable Intercreditor Agreement (including if consent to release all Liens on Collateral has been given by the Majority Agent, acting in accordance with the First Lien Financing Document(s) for the series of First Lien Obligations with respect to which it is acting in such capacity, pursuant to the First Lien Intercreditor Agreement).

(c) At the request of the Issuer, and upon delivery of an Officer’s Certificate and Opinion of Counsel delivered to the Trustee in accordance with in the requirements specified in this Indenture, the Trustee will execute and deliver any documents, instructions or instruments evidencing the consent of the Holders (and the Holders will be deemed to have consented to and authorized the Trustee to execute and deliver any such documentation, instructions or instruments) to any permitted release contemplated by Section 12.04(b). Each Holder of Notes, by its acceptance of a Note, is deemed to have irrevocably consented to and authorized the Trustee and the Collateral Agent to execute and deliver any such documentation, instructions or instruments relating to any such permitted release under this Indenture or the Security Documents.

(d) The Collateral Agent or the Trustee, as applicable, shall execute and deliver all such authorizations, instructions and other instruments and take such actions (and the Holders will be deemed to have consented to and authorized the Collateral Agent or the Trustee, as applicable, to execute and deliver any such authorization, instruction or instrument and take any such action) under the Security Documents or otherwise as may be reasonably requested in writing by the Issuer, at the cost of the Issuer, to evidence, confirm and effectuate any release of Collateral provided for in Section 12.04(b); provided that the Trustee and the Collateral Agent shall be entitled to receive an Opinion of Counsel and an Officer’s Certificate in connection with any such request of the Issuer related to the release of any Collateral.

Section 12.05 Suits to Protect the Collateral

Subject to the provisions of Article 7 and the Security Documents, the Trustee may or may direct the Collateral Agent to take all actions it determines in order to:

(a) enforce any of the terms of the Security Documents; and

 

145


(b) collect and receive any and all amounts payable in respect of the Obligations hereunder.

Subject to the provisions of the Security Documents, the Trustee and the Collateral Agent shall have power to institute and to maintain such suits and proceedings as the Trustee or the Collateral Agent may determine to prevent any impairment of the Collateral by any acts which may be unlawful or in violation of any of the Security Documents or this Indenture, and such suits and proceedings as the Trustee or the Collateral Agent may determine to preserve or protect its interests and the interests of the Holders in the Collateral. Nothing in this Section 12.05 shall be considered to impose any such duty or obligation to act on the part of the Trustee or the Collateral Agent.

Section 12.06 Authorization of Receipt of Funds by the Trustee Under the Security Documents.

Subject to the provisions of any Applicable Intercreditor Agreement, the Trustee is authorized to receive any funds for the Notes Parties distributed under the Security Documents, and to make further distributions of such funds to the Holders according to the provisions of this Indenture.

Section 12.07 Purchaser Protected.

No purchaser or grantee of any property or rights purporting to be released herefrom shall be bound to ascertain the authority of the Trustee or the Collateral Agent to execute the release or to inquire as to the existence of any conditions herein prescribed for the exercise of such authority; nor shall any purchaser or grantee of any property or rights permitted by this Indenture to be sold or otherwise disposed of by the Issuer or any Guarantor be under any obligation to ascertain or inquire into the authority of the Issuer or such Guarantor to make such sale or other disposition.

ARTICLE 13

MISCELLANEOUS

Section 13.01 Notices.

Any notice or communication by the Issuer, any Guarantor or the Trustee to the others is duly given if in writing and delivered in Person or by first class mail (registered or certified, return receipt requested), electronic mail or overnight air courier guaranteeing next day delivery, to the others’ address:

If to the Issuer and/or any Guarantor:

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

E-mail: [***]

Attention: Chief Financial Officer and General Counsel

 

146


With a copy to:

Davis Polk & Wardwell LLP

450 Lexington Avenue

New York, NY 10017

E-mail: [***]

Attention: [***]

If to the Trustee:

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

E-mail: [***]

Attention: Corporate Trust Administration

The Issuer, any Guarantor or the Trustee, by notice to the others, may designate additional or different addresses for subsequent notices or communications.

All notices and communications (other than those sent to Holders) will be deemed to have been duly given: at the time delivered by hand, if personally delivered; five Business Days after being deposited in the mail, postage prepaid, if mailed; when receipt acknowledged, if transmitted by electronic mail; and the next Business Day after timely delivery to the courier, if sent by overnight air courier guaranteeing next day delivery; provided that all notices and communications to the Trustee shall not be deemed received by the Trustee unless actually received by the Trustee at its address or electronic mail address set forth above.

Any notice or communication to a Holder will be mailed by first class mail, or by certified or registered mail, return receipt requested, or by overnight air courier guaranteeing next day delivery to its address shown on the register kept by the Registrar. Failure to mail a notice or communication to a Holder or any defect in it will not affect its sufficiency with respect to other Holders.

If a notice or communication is mailed in the manner provided above within the time prescribed, it is duly given, whether or not the addressee receives it.

If the Issuer mails a notice or communication to Holders, it will send a copy to the Trustee and each Agent at the same time by any of the means described above with respect to notice or communication by the Issuer.

Section 13.02 Certificate and Opinion as to Conditions Precedent.

Upon any request or application by the Issuer to the Trustee to take any action under any Note Document, the Issuer shall furnish to the Trustee:

(1) an Officer’s Certificate in form reasonably satisfactory to the Trustee (which must include the statements set forth in Section 13.03) stating that, in the opinion of the signers, all conditions precedent and covenants, if any, provided for in the relevant Note Document(s) relating to the proposed action have been complied with; and

 

147


(2) an Opinion of Counsel in form reasonably satisfactory to the Trustee (which must include the statements set forth in Section 13.03) stating that, in the opinion of such counsel, all such conditions precedent and covenants have been complied with, provided, that no such Opinion of Counsel shall be delivered on the date of this Indenture in connection with the original issuance of the initial Global Notes.

The Trustee shall, to the extent permitted by Sections 7.01 and 7.02, be entitled to rely upon, as conclusive evidence of compliance with the foregoing provisions the appropriate statements contained in such documents and such Opinion of Counsel.

Section 13.03 Statements Required in Certificate or Opinion.

Each certificate or opinion with respect to compliance with a condition or covenant provided for in this Indenture and must include:

(1) a statement that the Person making such certificate or opinion has read such covenant or condition;

(2) a brief statement as to the nature and scope of the examination or investigation upon which the statements or opinions contained in such certificate or opinion are based;

(3) a statement that, in the opinion of such Person, he or she has made such examination or investigation as is necessary to enable him or her to express an informed opinion as to whether or not such covenant or condition has been complied with; and

(4) a statement as to whether or not, in the opinion of such Person, such condition or covenant has been complied with.

Section 13.04 Rules by Trustee and Agents.

The Trustee may make reasonable rules for action by or at a meeting of Holders. The Registrar or Paying Agent may make reasonable rules and set reasonable requirements for its functions.

Section 13.05 No Personal Liability of Directors, Managers, Officers, Members, Partners, Employees and Equityholders.

No past, present or future director, officer, manager, employee, incorporator, member, partner or direct or indirect stockholder, member or unitholder of the Issuer or any Restricted Subsidiaries or of any of their direct or indirect parent companies, as such, will have any liability for any obligations of the Issuer or the Guarantors under the Notes, this Indenture, the Guarantees or any Security Documents, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability.

 

148


The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

Section 13.06 Governing Law; Waiver of Trial by Jury; Jurisdiction.

(a) THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THIS INDENTURE, THE NOTES AND THE GUARANTEES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5- 1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

(b) Each of the Issuer, any Guarantors and the Trustee, and each Holder of a Note, by its acceptance thereof, hereby irrevocably waives, to the fullest extent permitted by applicable law, any and all right it may have to trial by jury in any legal proceeding directly or indirectly arising out of or relating to this Indenture, the securities or the transactions contemplated hereby or thereby.

(c) Each of the Issuer and each Guarantor, if any, irrevocably consents and submits, for itself and in respect of any of its assets or property, to the non-exclusive jurisdiction of any court of the State of New York or any United States federal court sitting, in each case, in the Borough of Manhattan, the City of New York, New York, United States of America, and any appellate court from any thereof in any suit, action or proceeding that may be brought in connection with this Indenture or the securities, and waives any immunity from the jurisdiction of such courts. Each of the Issuer and each Guarantor, if any, irrevocably waives, to the fullest extent permitted by law, any objection to any such suit, action or proceeding that may be brought in such courts whether on the grounds of venue, residence or domicile or on the ground that any such suit, action or proceeding has been brought in an inconvenient forum. Each of the Issuer and each Guarantor, if any, agrees, to the fullest extent that it lawfully may do so, that final judgment in any such suit, action or proceeding brought in such a court shall be conclusive and binding upon the Issuer and any Guarantor, if any, as applicable, and each of the Issuer and any Guarantor, if any, waives, to the fullest extent permitted by law, any objection to the enforcement by any competent court in the Issuer’s and the applicable Guarantor’s, as applicable, jurisdiction of organization of judgments validly obtained in any such court in New York on the basis of such suit, action or proceeding; provided, however, that neither the Issuer nor any Guarantor waive, and the foregoing provisions of this sentence shall not constitute or be deemed to constitute a waiver of, (i) any right to appeal any such judgment, to seek any stay or otherwise to seek reconsideration or review of any such judgment or (ii) any stay of execution or levy pending an appeal from, or a suit, action or proceeding for reconsideration of, any such judgment.

Section 13.07 No Adverse Interpretation of Other Agreements.

This Indenture may not be used to interpret any other indenture, loan or debt agreement of the Issuer or its Subsidiaries or of any other Person. Any such indenture, loan or debt agreement may not be used to interpret this Indenture.

Section 13.08 Successors.

All agreements of the Issuer in this Indenture and the Notes will bind its successors. All agreements of the Trustee in this Indenture will bind its successors. All agreements of each Guarantor in this Indenture will bind its successors, except as otherwise provided in Article 10 hereof.

 

149


Section 13.09 Severability.

In case any provision in this Indenture or in the Notes is invalid, illegal or unenforceable, the validity, legality and enforceability of the remaining provisions will not in any way be affected or impaired thereby.

Section 13.10 Execution; Counterpart Originals.

The parties may manually or electronically sign any number of copies of this Indenture. Each signed copy will be an original, but all of them together represent the same agreement. The exchange of copies of this Indenture and of signature pages by electronic format (i.e., “pdf” or “tif”) transmission shall constitute effective execution and delivery of this Indenture as to the parties hereto and may be used in lieu of the original Indenture for all purposes. Signatures of the parties hereto transmitted by electronic format (i.e., “pdf” or “tif”) shall be deemed to be their original signatures for all purposes. Delivery of an executed Indenture by one party to any other party may be made by electronic mail (including any electronic signature complying with the New York Electronic Signatures and Records Act (N.Y. State Tech. §§ 301-309), as amended from time to time, or other applicable law), including DocuSign, or other transmission method, and the parties hereto agree that any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes.

Section 13.11 Table of Contents, Headings, etc.

The Table of Contents and Headings of the Articles and Sections of this Indenture have been inserted for convenience of reference only, are not to be considered a part of this Indenture and will in no way modify or restrict any of the terms or provisions hereof.

Section 13.12 Tax Matters. Each of the parties hereto agree to cooperate and to provide the other with such information as each may have in its possession to enable the determination of whether any payments pursuant to this Indenture are subject to the withholding requirements described in Section 1471(b) of the Code or otherwise imposed pursuant to Sections 1471 through 1474 of the Code and any regulations, or agreements thereunder or official interpretations thereof (“Applicable Tax Law”). The Trustee shall be entitled to make any withholding or deduction from payments under this Indenture to the extent necessary to comply with Applicable Tax Law.

[Signatures on following page]

 

150


SIGNATURES

Dated as of July 24, 2024

 

VENTURE GLOBAL LNG, INC.
By:   /s/ Jonathan W. Thayer
Name: Jonathan W. Thayer
Title: Chief Financial Officer

[Signature page to Indenture]


THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee and Collateral Agent
By:   /s/ Ann M. Dolezal
Name: Ann M. Dolezal
Title: Vice President

[Signature page to Indenture]


EXHIBIT A

[Face of Note]

 

[Insert the Global Note Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Private Placement Legend, if applicable pursuant to the provisions of the Indenture]

[Insert the Regulation S Temporary Note Legend, if applicable pursuant to the provisions of the indenture]

 

A-1


   CUSIP       2
   ISIN       3

7.00% Senior Secured Notes due 2030

 

No.         [Initially]4 $       

VENTURE GLOBAL LNG, INC.

promises to pay to [Cede & Co.]5 [       ] or registered assigns, the principal sum [of              UNITED STATES DOLLARS] or [as set forth on the Schedule of Exchanges of Interests in the Global Note attached hereto]6 on January 15, 2030.

 

Interest Payment Dates:    January 15 and July 15
Record Dates:    January 1 and July 1

Additional provisions of this Note are set forth on the other side of this Note.

 

  

 

2 

92332Y AE1 (Rule 144A); U9220N AG6 (Reg S).

3 

US92332YAE14 (Rule 144A); USU9220NAG61 (Reg S).

4 

Include only if the Note is issued in global form.

5 

Include only if the Note is issued in global form.

6 

Include only if the Note is issued in global form.

 

A-2


IN WITNESS HEREOF, the Issuer has caused this instrument to be duly executed.

Dated:         

 

VENTURE GLOBAL LNG, INC.
By:    
  Name:
  Title:

 

This is one of the Notes referred to in the within-mentioned Indenture:
The Bank of New York Mellon Trust Company, N.A., as Trustee
By:    
 

Authorized Signatory

 

A-3


[Back of Note]

7.00% Senior Secured Notes due 2030

Capitalized terms used herein have the meanings assigned to them in the Indenture referred to below unless otherwise indicated.

(1) INTEREST. Venture Global LNG, Inc., a Delaware corporation (the “Issuer”), promises to pay or cause to be paid interest on the principal amount of this Note at 7.00% per annum from [July 24, 2024]7 until maturity. The Issuer will pay interest, if any, semi-annually in arrears on January 15 and July 15 of each year, beginning on [January 15, 2025]8, or if any such day is not a Business Day, on the next succeeding Business Day (each, an “Interest Payment Date”). The Issuer will make each interest payment to the Holder of record of this Note on the immediately preceding January 1 and July 1 (whether or not a Business Day) (each, a “Record Date”). Interest on the Notes will accrue from the most recent date to which interest has been paid or, if no interest has been paid, from [July 24, 2024].9

Interest will be computed on the basis of a 360-day year comprised of twelve 30-day months.

(2) METHOD OF PAYMENT. The Issuer will pay interest on the Notes (except defaulted interest), if any, to the Persons who are registered Holders at the close of business on the January 1 or July 1 next preceding the Interest Payment Date, even if such Notes are canceled after such record date and on or before such Interest Payment Date, except as provided in Section 2.12 of the Indenture with respect to defaulted interest. The Notes will be payable as to principal, premium, if any, and interest, if any, at the office or agency of the Paying Agent and Registrar within the City and State of New York, or, at the option of the Issuer, payment of interest, if any, may be made by check mailed to the Holders at their addresses set forth in the register of Holders; provided that (a) all cash payments of principal, premium, if any, and interest with respect to Notes represented by Global Notes registered in the name of or held by DTC or its nominee will be made through the Paying Agent by wire transfer of immediately available funds to the accounts specified by the registered Holder or Holders thereof and (b) all cash payments of principal, premium, if any, and interest with respect to certificated Notes may, at the option of the Issuer, be made by wire transfer to a U.S. dollar account maintained by the payee with a bank in the United States of America if such Holder elects payment by wire transfer by giving written notice to the Trustee or the Paying Agent to such effect designating such account no later than 30 days immediately preceding the relevant due date for payment (or such other date as the Trustee may accept in its discretion). Such payment will be in such coin or currency of the United States of America as at the time of payment is legal tender for payment of public and private debts.

 

7 

In the case of Notes issued on the Issue Date.

8 

In the case of Notes issued on the Issue Date.

9 

In the case of Notes issued on the Issue Date.

 

A-4


(3) PAYING AGENT AND REGISTRAR. Initially, The Bank of New York Mellon Trust Company, N.A., the Trustee under the Indenture, will act as Paying Agent and Registrar. The Issuer may change the Paying Agent or Registrar without prior notice to the Holders. The Issuer or any of its Subsidiaries may act as Paying Agent or Registrar.

(4) INDENTURE. The Issuer issued the Notes under an Indenture, dated as of July 24, 2024 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among the Issuer, the Trustee and the Collateral Agent. The terms of the Notes include those stated in the Indenture. The Notes are subject to all such terms, and Holders are referred to the Indenture for a statement of such terms. To the extent any provision of this Note conflicts with the express provisions of the Indenture, the provisions of the Indenture shall govern and be controlling. The Notes are unsecured obligations of the Issuer. The Indenture does not limit the aggregate principal amount of Notes that may be issued thereunder.

(5) OPTIONAL REDEMPTION.

(a) At any time prior to January 15, 2027, the Issuer may on any one or more occasions redeem up to 40% of the aggregate principal amount of Notes issued under the Indenture, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 107.000% of the principal amount of the Notes redeemed, plus accrued and unpaid interest, if any, to the date of redemption with an amount not to exceed the amount of net cash proceeds from one or more Equity Offerings consummated after the Issue Date; provided that:

(i) at least 50% of the aggregate principal amount of Notes issued under the Indenture on the Issue Date (excluding Notes held by the Issuer and its Subsidiaries) remains outstanding immediately after the occurrence of such redemption (unless all such Notes are otherwise repurchased or redeemed pursuant to another provision described under Article 3 of the Indenture); and

(ii) the redemption occurs within 180 days of the date of the closing of such Equity Offerings.

(b) At any time prior to January 15, 2027, the Issuer may on any one or more occasions redeem all or a part of the Notes, upon not less than 10 nor more than 60 days’ notice, at a redemption price equal to 100% of the principal amount of the Notes redeemed, plus the Applicable Redemption Premium as of, and accrued and unpaid interest, if any, to the date of redemption.

(c) On or after January 15, 2027, the Issuer may on any one or more occasions redeem all or a part of the Notes, upon not less than 10 nor more than 60 days’ notice, at the redemption prices (expressed as percentages of principal amount) set forth below, plus accrued and unpaid interest, if any, on the Notes redeemed, to the applicable date of redemption, if redeemed during the twelve-month period beginning on January 15 of the years indicated below:

 

Year

   Percentage  

2027

     103.500%  

2028

     101.750%  

2029 and thereafter

     100.000%  

 

A-5


Unless the Issuer defaults in the payment of the redemption price, interest will cease to accrue on the Notes or portions thereof called for redemption on the applicable redemption date.

(6) MANDATORY REDEMPTION. The Issuer is not required to make mandatory redemption or sinking fund payments with respect to the Notes.

(7) REPURCHASE AT THE OPTION OF HOLDER.

(a) Upon the occurrence of a Change of Control Triggering Event, the Issuer will be required to make an offer (a “Change of Control Offer”) to each Holder to repurchase all or any part (equal to $2,000 or an integral multiple of $1,000 in excess thereof) of that Holder’s Notes at a purchase price in cash (the “Change of Control Payment”) equal to 101% of the aggregate principal amount of Notes repurchased, plus accrued and unpaid interest, if any, on the Notes repurchased to, but not including, the date of purchase, subject to the rights of Holders of Notes on the relevant record date to receive interest due on the relevant Interest Payment Date. Within thirty days following any Change of Control Triggering Event, the Issuer will mail, or deliver electronically if the Notes are held at DTC, a notice to each Holder setting forth the procedures governing the Change of Control Offer as required by the Indenture.

(b) The Issuer will be required to make a Collateral Asset Sale Offer or an Asset Sale Offer to the extent provided in Section 4.10 of the Indenture.

(8) NOTICE OF REDEMPTION. At least 10 days but not more than 60 days before a redemption date, the Issuer will mail or cause to be mailed, by first class mail (or, in the case of Global Notes, transmit with the procedures of the Depositary), a notice of redemption to each Holder (with a copy to the Trustee) whose Notes are to be redeemed at its registered address, except that redemption notices may be mailed or transmitted more than 60 days prior to a redemption date if the notice is issued in connection with a defeasance of the Notes or a satisfaction and discharge of the Indenture pursuant to Articles 8 or 11 thereof Notes and portions of Notes selected will be in amounts of $2,000 or whole multiples of $1,000 in excess thereof; except that if all of the Notes of a Holder are to be redeemed or purchased, the entire outstanding amount of Notes held by such Holder shall be redeemed or purchased.

Any such redemption may, at the Issuer’s discretion, be subject to one or more conditions precedent, including completion of any related Equity Offerings, Change of Control or other transaction. In addition, if such redemption is subject to the satisfaction of one or more conditions precedent, the related notice shall describe each such condition, and if applicable, shall state that, in the Issuer’s discretion, the date of redemption may be delayed until such time as any or all such conditions shall be satisfied or waived, or such redemption or purchase may not occur and such notice may be rescinded in the event that any or all such conditions shall not have been satisfied or waived by the date of redemption, or by the date of redemption as so delayed. In addition, the Issuer may provide in such notice that payment of the redemption price and performance of the Issuer’s obligations with respect to such redemption may be performed by another Person (it being understood that any such provision for payment by another Person will not relieve the Issuer and the Guarantors, if any, from their obligations with respect to such redemption).

 

A-6


(9) DENOMINATIONS, TRANSFER, EXCHANGE. The Notes are in registered form in denominations of $2,000 and integral multiples of $1,000 in excess thereof. The transfer of Notes may be registered and Notes may be exchanged as provided in the Indenture. The Registrar and the Trustee may require a Holder, among other things, to furnish appropriate endorsements and transfer documents and the Issuer may require a Holder to pay any taxes and fees required by law or permitted by the Indenture. The Issuer need not exchange or register the transfer of any Note or portion of a Note selected for redemption, except for the unredeemed portion of any Note being redeemed in part. Also, the Issuer need not exchange or register the transfer of any Notes for a period of 15 days before a selection of Notes to be redeemed or during the period between a record date and the next succeeding Interest Payment Date.

(10) PERSONS DEEMED OWNERS. The registered Holder may be treated as the owner of it for all purposes. Only registered Holders have rights under the Indenture.

(11) AMENDMENT, SUPPLEMENT AND WAIVER. Subject to certain exceptions, the Indenture, the Notes or the Guarantees may be amended or supplemented as provided in the Indenture.

(12) DEFAULTS AND REMEDIES. The Events of Default relating to the Notes are defined in Section 6.01 of the Indenture. If any Event of Default (other than an Event of Default of the type specified in clause (h) or (i) of Section 6.01 of the Indenture with respect to the Issuer) occurs and is continuing under the Indenture, the Trustee or the Holders of not less than 30% in aggregate principal amount of all of the then outstanding Notes may, by written notice to the Issuer and the Trustee, may declare all of the Notes to be due and payable immediately. Upon any such declaration, the Notes shall become due and payable immediately. Notwithstanding the foregoing, in the case of an Event of Default arising under clause (h) or (i) of Section 6.01 of the Indenture with respect to the Issuer, all outstanding Notes will become due and payable immediately without further action or notice. Holders may not enforce the Indenture, the Notes, the Security Documents or the Guarantees except as provided in the Indenture. Subject to certain limitations, Holders of a majority in aggregate principal amount of all the Notes then outstanding may direct the Trustee in its exercise of any trust or power.

(13) TRUSTEE DEALINGS WITH ISSUER. The Trustee, in its individual or any other capacity, may make loans to, accept deposits from, and perform services for the Issuer or its Affiliates, and may otherwise deal with the Issuer or its Affiliates, as if it were not the Trustee.

(14) GUARANTEES. The Issuer’s obligations under the Notes are fully and unconditionally guaranteed, jointly and severally, by the Guarantors, if any, to the extent set forth in Article 10 of the Indenture.

 

A-7


(15) SECURITY. The Notes and the related Guarantees, if any, will be secured by the Collateral on the terms and subject to the conditions set forth in the Indenture and the Security Documents. The Collateral Agent holds the Collateral in trust for the benefit of the Holders of the Notes, in each case pursuant to the Security Documents, the Collateral Agency Agreement and any Acceptable Intercreditor Agreement. Each Holder, by accepting this Note, consents and agrees to the terms of the Security Documents (including the provisions providing for the foreclosure and release of Collateral), the Collateral Agency Agreement and any Acceptable Intercreditor Agreement, each as may be in effect or may be amended from time to time in accordance with their terms and the Indenture, and authorizes and directs the Trustee, the Collateral Agent and any common collateral agent (if any) to enter into the Security Documents, the Collateral Agency Agreement and any Acceptable Intercreditor Agreement at any time after the Issue Date, if applicable, and to perform its obligations and exercise its rights thereunder in accordance therewith.

(16) NO RECOURSE AGAINST OTHERS. No director, officer, employee, incorporator or stockholder of the Issuer or any Guarantor, as such, will have any liability for any obligations of the Issuer or the Guarantors under the Notes, the Indenture, the Guarantees, or for any claim based on, in respect of, or by reason of, such obligations or their creation. Each Holder by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities under the federal securities laws.

(17) AUTHENTICATION. This Note will not be entitled to any benefit under the Indenture or be valid or obligatory for any purposes until authenticated by the manual signature of the Trustee or an authenticating agent.

(18) ABBREVIATIONS. Customary abbreviations may be used in the name of a Holder or an assignee, such as: TEN COM (= tenants in common), TEN ENT (= tenants by the entireties), JT TEN (= joint tenants with right of survivorship and not as tenants in common), CUST (= Custodian), and U/G/M/A (= Uniform Gifts to Minors Act).

(19) CUSIP NUMBERS AND ISINS. Pursuant to a recommendation promulgated by the Committee on Uniform Security Identification Procedures, the Issuer has caused CUSIP numbers and ISINs to be printed on the Notes, and the Trustee may use CUSIP numbers and ISINs in notices of redemption as a convenience to Holders. No representation is made as to the accuracy of such numbers either as printed on the Notes or as contained in any notice of redemption, and reliance may be placed only on the other identification numbers placed thereon.

(20) GOVERNING LAW. THE LAW OF THE STATE OF NEW YORK WILL GOVERN AND BE USED TO CONSTRUE THE INDENTURE, THE NOTES AND THE GUARANTEES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW.

The Issuer will furnish to any Holder upon written request and without charge a copy of the Indenture. Requests may be made to:

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

 

A-8


ASSIGNMENT FORM

To assign this Note, fill in the form below:

 

(I) or (we) assign and transfer this Note to:                                              
  (Insert assignee’s legal name)

 

 

(Insert assignee’s soc. sec. or tax I.D. no.)

 

 

 

 

 

 

(Print or type assignee’s name, address and zip code)

and irrevocably appoint                                           to transfer this Note on the books of the Issuer. The agent may substitute another to act for him.

Date:       

 

Your Signature:    
(Sign exactly as your name appears on the face of this Note)

Signature Guarantee*:                

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A-9


OPTION OF HOLDER TO ELECT PURCHASE

If you want to elect to have this Note purchased by the Issuer pursuant to Section 4.10 or 4.15 of the Indenture, check the appropriate box below:

 

  

☐ Section 4.10

  

☐ Section 4.15

  
        

If you want to elect to have only part of the Note purchased by the Issuer pursuant to Section 4.10 or Section 4.15 of the Indenture, state the amount you elect to have purchased:

$         

Date:       

 

Your Signature:    
(Sign exactly as your name appears on the face of this Note)
Tax Identification No.:    

Signature Guarantee*:             

 

 

*

Participant in a recognized Signature Guarantee Medallion Program (or other signature guarantor acceptable to the Trustee).

 

A-10


SCHEDULE OF EXCHANGES OF INTERESTS IN THE GLOBAL NOTE *

The initial outstanding principal amount of this Global Note is $     . The following exchanges of a part of this Global Note for an interest in another Global Note or for a Definitive Note, or exchanges of a part of another Global Note or Definitive Note for an interest in this Global Note, have been made:

 

Date of Exchange

  

Amount of decrease in
Principal Amount of
this Global Note

  

Amount of increase in
Principal Amount of
this Global Note

  

Principal Amount
of this Global Note
following such decrease
(or increase)

  

Signature of authorized
officer of Trustee or
Custodian

 

*

This schedule should be included only if the Note is issued in global form.

 

A-12


EXHIBIT B

FORM OF CERTIFICATE OF TRANSFER

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

Re: 7.00% Senior Secured Notes due 2030

Reference is hereby made to the Indenture, dated as of July 24, 2024 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

           , (the “Transferor”) owns and proposes to transfer the Note[s] or interest in such Note[s] specified in Annex A hereto, in the principal amount of $        in such Note[s] or interests (the “Transfer”), to           (the “Transferee”), as further specified in Annex A hereto. In connection with the Transfer, the Transferor hereby certifies that:

[CHECK ALL THAT APPLY]

1. ☐ Check if Transferee will take delivery of a beneficial interest in the 144A Global Note or a Restricted Definitive Note pursuant to Rule 144A. The Transfer is being effected pursuant to and in accordance with Rule 144A under the Securities Act of 1933, as amended (the “Securities Act”), and, accordingly, the Transferor hereby further certifies that the beneficial interest or Definitive Note is being transferred to a Person that the Transferor reasonably believes is purchasing the beneficial interest or Definitive Note for its own account, or for one or more accounts with respect to which such Person exercises sole investment discretion, and such Person and each such account is a “qualified institutional buyer” within the meaning of Rule 144A in a transaction meeting the requirements of Rule 144A, and such Transfer is in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the 144A Global Note and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

 

B-1


2. ☐ Check if Transferee will take delivery of a beneficial interest in the Regulation S Temporary Global Note, the Regulation S Permanent Global Note or a Restricted Definitive Note pursuant to Regulation S. The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and, accordingly, the Transferor hereby further certifies that (i) the Transfer is not being made to a Person in the United States and (x) at the time the buy order was originated, the Transferee was outside the United States or such Transferor and any Person acting on its behalf reasonably believed and believes that the Transferee was outside the United States or (y) the transaction was executed in, on or through the facilities of a designated offshore securities market and neither such Transferor nor any Person acting on its behalf knows that the transaction was prearranged with a buyer in the United States, (ii) no directed selling efforts have been made in contravention of the requirements of Rule 903(b) or Rule 904(b) of Regulation S under the Securities Act, (iii) the transaction is not part of a plan or scheme to evade the registration requirements of the Securities Act and (iv) if the proposed transfer is being made prior to the expiration of the Restricted Period, the transfer is not being made to a U.S. Person or for the account or benefit of a U.S. Person (other than an Initial Purchaser). Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on Transfer enumerated in the Private Placement Legend printed on the Regulation S Permanent Global Note, the Regulation S Temporary Global Note, and/or the Restricted Definitive Note and in the Indenture and the Securities Act.

3. ☐ Check and complete if Transferee will take delivery of a beneficial interest in the IAI Global Note or a Restricted Definitive Note pursuant to any provision of the Securities Act other than Rule 144A or Regulation S. The Transfer is being effected in compliance with the transfer restrictions applicable to beneficial interests in Restricted Global Notes and Restricted Definitive Notes and pursuant to and in accordance with the Securities Act and any applicable blue sky securities laws of any state of the United States, and accordingly the Transferor hereby further certifies that (check one):

(a) ☐ such Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act;

or

(b) ☐ such Transfer is being effected to the Issuer or a subsidiary thereof; or

(c) ☐ such Transfer is being effected pursuant to an effective registration statement under the Securities Act and in compliance with the prospectus delivery requirements of the Securities Act;

or

 

B-2


(d) ☐ such Transfer is being effected to an Institutional Accredited Investor and pursuant to an exemption from the registration requirements of the Securities Act other than Rule 144A, Rule 144, Rule 903 or Rule 904, and the Transferor hereby further certifies that it has not engaged in any general solicitation within the meaning of Regulation D under the Securities Act and the Transfer complies with the transfer restrictions applicable to beneficial interests in a Restricted Global Note or Restricted Definitive Notes and the requirements of the exemption claimed, which certification is supported by (1) a certificate executed by the Transferee in the form of Exhibit D to the Indenture and (2) if such Transfer is in respect of a principal amount of Notes at the time of transfer of less than $250,000, an Opinion of Counsel provided by the Transferor or the Transferee (a copy of which the Transferor has attached to this certification), to the effect that such Transfer is in compliance with the Securities Act. Upon consummation of the proposed transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the IAI Global Note and/or the Restricted Definitive Notes and in the Indenture and the Securities Act.

4. Check if Transferee will take delivery of a beneficial interest in an Unrestricted Global Note or of an Unrestricted Definitive Note.

(a) ☐ Check if Transfer is pursuant to Rule 144. (i) The Transfer is being effected pursuant to and in accordance with Rule 144 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

(b) ☐ Check if Transfer is Pursuant to Regulation S. (i) The Transfer is being effected pursuant to and in accordance with Rule 903 or Rule 904 under the Securities Act and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any state of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will no longer be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes, on Restricted Definitive Notes and in the Indenture.

(c) ☐ Check if Transfer is Pursuant to Other Exemption. (i) The Transfer is being effected pursuant to and in compliance with an exemption from the registration requirements of the Securities Act other than Rule 144, Rule 903 or Rule 904 and in compliance with the transfer restrictions contained in the Indenture and any applicable blue sky securities laws of any State of the United States and (ii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act. Upon consummation of the proposed Transfer in accordance with the terms of the Indenture, the transferred beneficial interest or Definitive Note will not be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Global Notes or Restricted Definitive Notes and in the Indenture.

 

B-3


This certificate and the statements contained herein are made for your benefit and the benefit of the Issuer.

 

 

[Insert Name of Transferor]
By:  

 

  Name:
  Title:

 

Dated:  

 

 

B-4


ANNEX A TO CERTIFICATE OF TRANSFER

 

1.

The Transferor owns and proposes to transfer the following:

[CHECK ONE OF (a) OR (b)]

 

(a)

☐ a beneficial interest in the:

 

  (i)

☐ 144A Global Note (CUSIP     ), or

 

  (ii)

☐ Regulation S Global Note (CUSIP    ), or

 

  (iii)

☐ IAI Global Note (CUSIP     ); or

 

(b)

☐ a Restricted Definitive Note.

 

2.

After the Transfer the Transferee will hold:

[CHECK ONE]

 

(a)

☐ a beneficial interest in the:

 

  (i)

☐ 144A Global Note (CUSIP     ), or

 

  (ii)

☐ Regulation S Global Note (CUSIP     ), or

 

  (iii)

☐ IAI Global Note (CUSIP     ); or

 

  (iv)

☐ Unrestricted Global Note (CUSIP     ); or

 

(b)

☐ a Restricted Definitive Note; or

 

(c)

☐ an Unrestricted Definitive Note,

in accordance with the terms of the Indenture.

 

B-5


EXHIBIT C

FORM OF CERTIFICATE OF EXCHANGE

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

Re: 7.00% Senior Secured Notes due 2030

(CUSIP [  ]10)

Reference is hereby made to the Indenture, dated as of July 24, 2024 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

            , (the “Owner”) owns and proposes to exchange the Note[s] or interest in such Note[s] specified herein, in the principal amount of $ in such Note[s] or interests (the “Exchange”). In connection with the Exchange, the Owner hereby certifies that:

1. Exchange of Restricted Definitive Notes or Beneficial Interests in a Restricted Global Note for Unrestricted Definitive Notes or Beneficial Interests in an Unrestricted Global Note

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to beneficial interest in an Unrestricted Global Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a beneficial interest in an Unrestricted Global Note in an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Global Notes and pursuant to and in accordance with the Securities Act of 1933, as amended (the “Securities Act”), (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest in an Unrestricted Global Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

 

10 

92332Y AE1 (Rule 144A); U9220N AG6 (Reg S).

 

C-1


(b) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Unrestricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(c) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in an Unrestricted Global Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for a beneficial interest in an Unrestricted Global Note, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the beneficial interest is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

(d) ☐ Check if Exchange is from Restricted Definitive Note to Unrestricted Definitive Note. In connection with the Owner’s Exchange of a Restricted Definitive Note for an Unrestricted Definitive Note, the Owner hereby certifies (i) the Unrestricted Definitive Note is being acquired for the Owner’s own account without transfer, (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to Restricted Definitive Notes and pursuant to and in accordance with the Securities Act, (iii) the restrictions on transfer contained in the Indenture and the Private Placement Legend are not required in order to maintain compliance with the Securities Act and (iv) the Unrestricted Definitive Note is being acquired in compliance with any applicable blue sky securities laws of any state of the United States.

1. Exchange of Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes for Restricted Definitive Notes or Beneficial Interests in Restricted Global Notes

(a) ☐ Check if Exchange is from beneficial interest in a Restricted Global Note to Restricted Definitive Note. In connection with the Exchange of the Owner’s beneficial interest in a Restricted Global Note for a Restricted Definitive Note with an equal principal amount, the Owner hereby certifies that the Restricted Definitive Note is being acquired for the Owner’s own account without transfer. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the Restricted Definitive Note issued will continue to be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the Restricted Definitive Note and in the Indenture and the Securities Act.

 

C-2


(b) ☐ Check if Exchange is from Restricted Definitive Note to beneficial interest in a Restricted Global Note. In connection with the Exchange of the Owner’s Restricted Definitive Note for a beneficial interest in the [CHECK ONE] ☐ 144A Global Note, ☐ Regulation

S Global Note, ☐ IAI Global Note with an equal principal amount, the Owner hereby certifies (i) the beneficial interest is being acquired for the Owner’s own account without transfer and (ii) such Exchange has been effected in compliance with the transfer restrictions applicable to the Restricted Global Notes and pursuant to and in accordance with the Securities Act, and in compliance with any applicable blue sky securities laws of any state of the United States. Upon consummation of the proposed Exchange in accordance with the terms of the Indenture, the beneficial interest issued will be subject to the restrictions on transfer enumerated in the Private Placement Legend printed on the relevant Restricted Global Note and in the Indenture and the Securities Act.

This certificate and the statements contained herein are made for your benefit and the benefit of the Issuer.

 

 

[Insert Name of Transferor]

By:

   
 

Name:

 

Title:

Dated:          

 

C-3


EXHIBIT D

FORM OF CERTIFICATE FROM

ACQUIRING INSTITUTIONAL ACCREDITED INVESTOR

Venture Global LNG, Inc.

1001 19th Street North, Suite 1500

Arlington, VA 22209

Attention: Chief Financial Officer and General Counsel

The Bank of New York Mellon Trust Company, N.A.

601 Travis Street, 16th floor

Houston, TX 77002

Attention: Corporate Trust Administration

Re: 7.00% Senior Secured Notes due 2030

Reference is hereby made to the Indenture, dated as of July 24, 2024 (as amended, supplemented or otherwise modified from time to time, the “Indenture”), among Venture Global LNG, Inc., as issuer (the “Issuer”), the Guarantors party thereto and The Bank of New York Mellon Trust Company, N.A., as Trustee and Collateral Agent. Capitalized terms used but not defined herein shall have the meanings given to them in the Indenture.

In connection with our proposed purchase of $      aggregate principal amount of:

 

  (a)

☐ a beneficial interest in a Global Note, or

 

  (b)

☐ a Definitive Note,

we confirm that:

1. We understand that any subsequent transfer of the Notes or any interest therein is subject to certain restrictions and conditions set forth in the Indenture and the undersigned agrees to be bound by, and not to resell, pledge or otherwise transfer the Notes or any interest therein except in compliance with, such restrictions and conditions and the Securities Act of 1933, as amended (the “Securities Act”).

2. We understand that the offer and sale of the Notes have not been registered under the Securities Act, and that the Notes and any interest therein may not be offered or sold except as permitted in the following sentence. We agree, on our own behalf and on behalf of any accounts for which we are acting as hereinafter stated, that if we should sell the Notes or any interest therein, we will do so only (A) to the Issuer or any subsidiary thereof, (B) in accordance with Rule 144A under the Securities Act to a “qualified institutional buyer” (as defined therein), (C) to an institutional “accredited investor” (as defined below) that, prior to such transfer, furnishes (or has furnished on its behalf by a U.S. broker-dealer) to you and to the Issuer a signed letter substantially in the form of this letter and, if such transfer is in respect of a principal amount of Notes, at the time of transfer of less than $250,000, an Opinion of Counsel in form reasonably acceptable to the

 

D-1


Issuer to the effect that such transfer is in compliance with the Securities Act, (D) outside the United States in accordance with Rule 904 of Regulation S under the Securities Act, (E) pursuant to the provisions of Rule 144 under the Securities Act or (F) pursuant to an effective registration statement under the Securities Act, and we further agree to provide to any Person purchasing the Definitive Note or beneficial interest in a Global Note from us in a transaction meeting the requirements of clauses (A) through (E) of this paragraph a notice advising such purchaser that resales thereof are restricted as stated herein.

3. We understand that, on any proposed resale of the Notes or beneficial interest therein, we will be required to furnish to you and the Issuer such certifications, legal opinions and other information as you and the Issuer may reasonably require to confirm that the proposed sale complies with the foregoing restrictions. We further understand that the Notes purchased by us will bear a legend to the foregoing effect.

4. We are an institutional “accredited investor” (as defined in Rule 501(a)(1), (2), (3) or (7) of Regulation D under the Securities Act) and have such knowledge and experience in financial and business matters as to be capable of evaluating the merits and risks of our investment in the Notes, and we and any accounts for which we are acting are each able to bear the economic risk of our or its investment.

5. We are acquiring the Notes or beneficial interest therein purchased by us for our own account or for one or more accounts (each of which is an institutional “accredited investor”) as to each of which we exercise sole investment discretion.

You and the Issuer are entitled to rely upon this letter and are irrevocably authorized to produce this letter or a copy hereof to any interested party in any administrative or legal proceedings or official inquiry with respect to the matters covered hereby.

 

 

[Insert Name of Accredited Investor]

By:

   
 

Name:

 

Title:

Dated:           

 

D-2


EXHIBIT E

FORM OF SUPPLEMENTAL INDENTURE

TO BE DELIVERED BY SUBSEQUENT GUARANTORS

[Omitted]


EXHIBIT F to the Indenture

[FORM OF] JUNIOR LIEN INTERCREDITOR AGREEMENT

[Omitted]

Exhibit 10.98

EXECUTION DRAFT

Venture Global Partners, LLC

1001 19th Street North

Suite 1200

Arlington, VA 22209

Attention: Robert Pender, Managing Partner

 

Re:

VGC Management Services Agreement

Gentlemen:

Venture Global LNG, Inc. (“VGLNG”) (a) is developing through its subsidiary, Venture Global Calcasieu Pass, LLC, a liquefied natural gas (“LNG”) export project to be located directly on the Calcasieu Ship Channel south of Lake Charles, Louisiana, currently anticipated to consist of an approximately ten million tons per annum (nameplate capacity) liquefaction plant, a power plant, two 200,000 cubic meter (m3) LNG storage tanks, and an LNG berthing dock that would accommodate vessels up to 185,000 cubic meters (m3) in capacity (the “Calcasieu Pass Project”) and (b) is developing, through its subsidiaries, additional LNG export projects along the Gulf of Mexico (each a “Project” the collectively, the “Projects”).

VGLNG and Venture Global Commodities, LLC (the “Company”) are parties to that certain Amended and Restated Agreement for Excess Capacity, dated as of December 2, 2014 (the “Excess Capacity Agreement”), which includes the exclusive right for the Company to purchase excess capacity from the Calcasieu Pass Project, each of the other Projects and any expansion of any Project developed by VGLNG.

Each of the Company and VGP may be referred to herein individually as a “Party” and collectively as the “Parties.”

In recognition of the unique capabilities of VGP with respect to project development, finance and capital markets, regulatory, permitting and contractual matters, as well as VGP’s unique industry relationships, good will, understanding of natural gas and LNG commodities markets, business development plans and growth ideas, and the Company’s continuing need for assistance, support and strategic advice from VGP with respect to such unique capabilities in connection with the optimization of the Company’s rights and obligations under the Excess Capacity Agreement and the purchase and sale of excess capacity from the Projects under the Excess Capacity Agreement and the associated agreements entered into thereunder, the Company desires VGP to provide such assistance, support and strategic advice to the Company with respect to such unique capabilities (altogether, “Management Services”) through this management services agreement (“VGC Management Services Agreement”) and VGP desires to provide such Management Services to and for the benefit of the Company.


EXECUTION DRAFT

Accordingly, in consideration of the premises and the agreements, provisions and covenants herein contained, the Parties, intending to be legally bound, agree as follows:

1. The Parties hereby enter into this definitive and binding VGC Management Services Agreement for the provision by VGP to the Company of Management Services, as may be requested by the Company from time to time, for a term which commenced as of December 1, 2014 and shall terminate upon the later to occur of (1) the expiration of the useful life of all the Projects, as such Projects may be modified, expanded, repaired, or replaced by VGLNG, its subsidiaries or affiliates, and (2) twenty-five (25) years after the commercial operations date of the last Project developed by VGLNG, its subsidiaries or affiliates to achieve commercial operations; provided that the term shall be automatically renewable on a year-to-year basis thereafter unless either Party provides not less than one year prior written notice to terminate.

2. VGP shall cause personnel providing the Management Services to perform such Management Services with the same degree of care, skill, confidentiality and diligence with which such personnel perform similar services for VGP. VGP shall provide the Management Services as requested from time to time by the Company in accordance with the reasonable advance requests provided by the authorized representatives of the Company, or their designees, and VGP shall be entitled to rely upon any written or oral instructions received from those individuals who VGP reasonably believes to be such authorized representatives or designees.

3. The Parties agree that VGP shall provide such Management Services as an independent contractor for and on behalf of the Company, and nothing in this VGC Management Services Agreement shall at any time be construed to create the relationship of employer and employee, partnership, principal and agent, broker or finder, or joint venturers as between the Parties.

4. For the availability of VGP to perform the Management Services, the Company shall pay to VGP a monthly fee, in advance, in an amount equal to, for each month from the first day the commercial operations date has been achieved (“COD”) by the Calcasieu Pass Project and thereafter for the term hereof, Five Hundred Thousand Dollars (US$500,000) per month (each a “Service Fee”). The Service Fee shall be escalated each year for inflation. The Service Fee to be paid in any year shall be escalated annually for any inflation at the commencement of each year during the term by multiplying the initial Service Fee (and any escalated Service Fee thereafter) times a fraction, the numerator of which is the arithmetic average of the CPI for the twelve months preceding such calendar year and the denominator is the arithmetic average of the CPI for the last full calendar year period preceding COD. As used in this VGC Management Services Agreement, “CPI” means the US Department of Labor Statistics Consumer Price Index published by the Bureau of Labor Statistics, United States Department of Labor, Washington, DC (http://www.bls.gov/cpi). In addition to the Service Fee, the Company shall reimburse VGP for all reasonable out-of-pocket expenses incurred in connection with the performance of the Management Services.

5. Disputes arising under this VGC Management Services Agreement that are not resolved through informal discussion may be submitted to binding arbitration in Washington, DC conducted in accordance with the rules of the American Arbitration Association.


EXECUTION DRAFT

6. Notwithstanding any provision herein to the contrary, the maximum aggregate liability of VGP under or in connection with this VGC Management Services Agreement, whether in contract, negligence or other tort, non-performance or breach of statutory duty, under indemnity or otherwise, shall be an amount equal to the Service Fee payable in respect of the most recent twelve months. Neither Party shall be liable for any indirect, incidental, special, exemplary, consequential or punitive damages or losses of any nature howsoever arising, including loss of income or profits, under or in connection with this VGC Management Services Agreement, whether in contract, negligence or other tort, non-performance, breach of statutory duty, under indemnity or otherwise.

7. This VGC Management Services Agreement contains the entire understanding between the Parties with respect to the subject matter hereof and supersedes and replaces any other agreement or understanding between the Parties in respect of the subject matter.

8. No Party may assign this VGC Management Services Agreement or any of its rights or obligations hereunder to any other person or entity without the prior written consent of the other Party, which consent shall not be unreasonably withheld or delayed; provided VGP may assign its rights to receive any and all of its Service Fees hereunder.

9. This VGC Management Services Agreement shall be governed by and construed in accordance with the laws of the State of New York, without giving effect to the choice of law provisions thereof that would require the application of the laws of any other jurisdiction.

10. This VGC Management Services Agreement is a legally binding agreement of the Parties and shall inure to the benefit of the Parties and their respective successors and permitted assigns.

11. No amendment or modification of this VGC Management Services Agreement shall be binding upon the Parties unless in writing and signed by both Parties.

12. Each Party will bear its own costs in relation to the preparation, negotiation and execution of this VGC Management Services Agreement and any other documents related thereto.

13. No person that is not a party to this VGC Management Services Agreement shall have any right to rely upon, make any claim or otherwise seek to enforce, whether directly or indirectly, any term or provision of this VGC Management Services Agreement.

14. This VGC Management Services Agreement does not create any partnership, joint venture or other legal entity, nor does it create any agency relationship.

15. This VGC Management Services Agreement may be executed in one or more counterparts, and all counterparts when executed shall form part of and constitute one and the same original agreement.

16. This VGC Management Services Agreement shall be effective as of December 1, 2014.

 


EXECUTION DRAFT

If the foregoing is in accordance with our mutual understanding and if this VGC Management Services Agreement constitutes a satisfactory basis for proceeding with respect to the matters described herein, please so indicate by signing this VGC Management Services Agreement in the places indicated below and by returning the executed copy to us.

 

Very truly yours,

VENTURE GLOBAL COMMODITIES, LLC

By:

 

/s/ Robert B. Pender

Name:

 

Robert B. Pender

Title:

  Managing Partner, Venture Global Partners, LLC, as sole member of Venture Global Commodities, LLC

 

Acknowledged and agreed to:

VENTURE GLOBAL PARTNERS, LLC

By:

 

/s/ Michael Sabel

Name:

 

Michael Sabel

Title:

 

Managing Partner, Venture Global Partners, LLC

Exhibit 10.99

EXECUTION DRAFT

April 20, 2015

Venture Global Partners, LLC

1101 30th Street, NW

Suite 500

Washington, DC 20007

Attention: Robert Pender, Managing Partner

 

Re:

Second Amended and Restated Management Services Agreement

Gentlemen:

Venture Global LNG, Inc. (f/k/a Venture Global LNG, LLC) (the “Company”) (a) is developing through its subsidiary, Venture Global Calcasieu Pass, LLC, a liquefied natural gas (“LNG”) export project to be located directly on the Calcasieu Ship Channel south of Lake Charles, Louisiana, currently anticipated to consist of an approximately ten million tons per annum liquefaction plant, a power plant, two 200,000 cubic meter (m3) LNG storage tanks, and an LNG berthing dock that would accommodate vessels up to 185,000 cubic meters (m3) in capacity and (b) is anticipating developing, through its subsidiaries, additional LNG export projects along the Gulf of Mexico (each a “Project” the collectively, the “Projects”).

The Company and Venture Global Partners, LLC (“VGP”) are parties to that certain Management Services Agreement, dated as of June 27, 2014, as amended and restated pursuant to that certain Amended and Restated Management Services Agreement, dated as of December 2, 2015 (the “Original Management Services Agreement”) and the Company and VGP desire to further amend and restate the Original Management Services Agreement as set forth herein. Each of the Company and VGP may be referred to herein individually as a “Party” and collectively as the “Parties.”

In recognition of the unique capabilities of VGP with respect to project development, finance and capital market, regulatory, and contractual matters, as well as VGP’s unique industry relationships, good will, business development plans and growth ideas, and the Company’s continuing need for assistance and support from VGP with respect to such unique capabilities in connection with the development, engineering, permitting, financing, construction and operation of the Projects, the Company desires VGP to provide such assistance and support to the Company with respect to such unique capabilities (altogether, “Management Services”) through this Second Amended and Restated Management Services Agreement (this “Management Services Agreement”) and VGP desires to provide such Management Services to and for the benefit of the Company, its subsidiaries, and the Projects.


EXECUTION DRAFT

Accordingly, in consideration of the premises and the agreements, provisions and covenants herein contained, the Parties, intending to be legally bound, agree as follows:

1. The Parties hereby enter into this definitive and binding Management Services Agreement for the provision by VGP to the Company of Management Services, as may be requested by the Company from time to time, for a term which shall commence as of December 1, 2014 and terminate upon the later to occur of (1) the expiration of the useful life of all the Projects, as such Projects may be modified, expanded, repaired, or replaced by the Company or its subsidiaries, and (2) twenty-five (25) years after the commercial operations date of the last Project developed by the Company or its subsidiaries to achieve commercial operations; provided that the term shall be automatically renewable on a year-to-year basis thereafter unless either Party provides not less than one year prior written notice to terminate.

2. VGP shall cause personnel providing the Management Services to perform such Management Services with the same degree or care, skill, confidentiality and diligence with which such personnel perform similar services for VGP. VGP shall provide the Management Services as requested from time to time by the Company in accordance with the reasonable advance requests provided by the authorized representatives of the Company, or their designees, and VGP shall be entitled to rely upon any written or oral instructions received from those individuals who VGP reasonably believes to be such authorized representatives or designees.

3. The Parties agree that VGP shall provide such Management Services as an independent contractor for and on behalf of the Company, and nothing in this Management Services Agreement shall at any time be construed to create the relationship of employer and employee, partnership, principal and agent, broker or finder, or joint venturers as between the Parties.

4. The Company shall pay to VGP a monthly fee, in advance, for the availability of VGP to perform the Management Services equal to: (1) for each month prior to the first positive final investment decision by the Company, or its applicable subsidiary, to construct a Project (“FID”), Two Hundred Eight Thousand Three Hundred Thirty-Three Dollars and Thirty-Three Cents (US$208,333.33) per month; and (2) from FID and thereafter for the term hereof, Five Hundred Thousand Dollars (US$500,000) per month (each a “Service Fee”). The Service Fee described in clause (2) of the preceding sentence shall be escalated annually for any inflation at the commencement of each year during the term by multiplying such Service Fee times a fraction, the numerator of which is the arithmetic average of the CPI for the twelve months preceding such calendar year and the denominator is the arithmetic average of the CPI for the twelve months period immediately preceding FID. As used in this Management Services Agreement, “CPI” means the US Department of Labor Statistics Consumer Price Index published by the Bureau of Labor Statistics, United States Department of Labor, Washington, DC (http://www.bls.gov/cpi). In addition to the Service Fee, the Company shall reimburse VGP for all reasonable out-of-pocket expenses incurred in connection with the performance of the Management Services.

5. Disputes arising under this Management Services Agreement that are not resolved through informal discussion may be submitted to binding arbitration in Washington, DC conducted in accordance with the rules of the American Arbitration Association.


EXECUTION DRAFT

6. Notwithstanding any provision herein to the contrary, the maximum aggregate liability of VGP under or in connection with this Management Services Agreement, whether in contract, negligence or other tort, non-performance or breach of statutory duty, under indemnity or otherwise, shall be an amount equal to the Service Fee payable in respect of the most recent twelve months. Neither Party shall be liable for any indirect, incidental, special, exemplary, consequential or punitive damages or losses of any nature howsoever arising, including loss of income or profits, under or in connection with this Management Services Agreement, whether in contract, negligence or other tort, non-performance, breach of statutory duty, under indemnity or otherwise.

7. This Management Services Agreement contains the entire understanding between the Parties with respect to the subject matter hereof, and supersedes and replaces any other agreement or understanding between the Parties in respect of the subject matter hereof dated prior to the date of this Management Services Agreement.

8. No Party may assign this Management Services Agreement or any of its rights or obligations hereunder to any other person or entity without the prior written consent of the other Party, which consent shall not be unreasonably withheld or delayed; provided VGP may assign its rights to receive any and all of its Service Fees hereunder.

9. This Management Services Agreement shall be governed by and construed in accordance with the laws of the State of New York, without giving effect to the choice of law provisions thereof that would require the application of the laws of any other jurisdiction.

10. This Management Services Agreement is a legally binding agreement of the Parties, and shall inure to the benefit of the Parties and their respective successors and permitted assigns.

11. No amendment or modification of this Management Services Agreement shall be binding upon the Parties unless in writing and signed by both Parties.

12. Each Party will bear its own costs in relation to the preparation, negotiation and execution of this Management Services Agreement and any other documents related thereto.

13. No person that is not a party to this Management Services Agreement shall have any right to rely upon, make any claim or otherwise seek to enforce, whether directly or indirectly, any term or provision of this Management Services Agreement.

14. This Management Services Agreement does not create any partnership, joint venture or other legal entity, nor does it create any agency relationship.

15. This Management Services Agreement may be executed in one or more counterparts, and all counterparts when executed shall form part of and constitute one and the same original agreement.


EXECUTION DRAFT

If the foregoing is in accordance with our mutual understanding and if this Management Services Agreement constitutes a satisfactory basis for proceeding with respect to the matters described herein, please so indicate by signing this Amended and Restated Management Services Agreement in the places indicated below and by returning the executed copy to us.

 

Very truly yours,
VENTURE GLOBAL LNG, Inc.

By:

 

/s/ William M. Wicker

Name:

 

William M. Wicker

Title:

 

Chief Executive Officer

 

Acknowledged and agreed to:
VENTURE GLOBAL PARTNERS, LLC

By:

 

/s/ Robert B. Pender

Name:

 

Robert B. Pender

Title:

 

Managing Partner

Exhibit 10.100

CERTIFICATE OF DESIGNATIONS

OF

9.00% SERIES A FIXED-RATE RESET CUMULATIVE REDEEMABLE

PERPETUAL PREFERRED STOCK

OF

VENTURE GLOBAL LNG, INC.

Pursuant to Section 151 of the General Corporation Law of the State of Delaware (the “DGCL”), Venture Global LNG, Inc., a corporation duly organized and validly existing under the DGCL (the “Corporation”), in accordance with the provisions of Section 103 thereof, does hereby submit the following:

WHEREAS, the Sixth Amended and Restated Certificate of Incorporation of the Corporation (as amended, restated, supplemented, or otherwise modified from time to time, the “Certificate of Incorporation”) authorizes the issuance of 3,000,000 shares of preferred stock, par value $0.01 per share (the “Preferred Stock”), of the Corporation, issuable from time to time in one or more classes or series, and authorizes the Board of Directors (the “Board”) of the Corporation, subject to the limitations under applicable Delaware law, to (i) determine the designations, powers, preferences and relative, participating, optional or other rights, if any, and the qualifications, limitations or restrictions thereof, if any, with respect to each such class or series of Preferred Stock, (ii) fix the number of shares of any class or series of Preferred Stock and (iii) issue shares of Preferred Stock, in each case without any stockholder action or vote; and

WHEREAS, it is the desire of the Board to establish and fix the number of shares to be included in a new series of Preferred Stock and the designations, powers, preferences and relative, participating, optional and other rights, and the qualifications, limitations and restrictions of such new series.

NOW, THEREFORE, BE IT RESOLVED, that the Board does hereby provide authority for the Corporation to issue and designate 3,000,000 shares of the Preferred Stock to be known as “9.00% Series A Fixed-Rate Reset Cumulative Redeemable Perpetual Preferred Stock” (the “Series A Preferred Shares”) and does hereby in this certificate of designations (this “Certificate of Designations”) establish and fix and herein state and express the designations, powers, preferences and relative, participating, optional and other rights, and the qualifications, limitations and restrictions of such Series A Preferred Shares as follows:

Section 1. General Matters; Ranking.

Each Series A Preferred Share shall be identical in all respects to every other Series A Preferred Share. The Series A Preferred Shares, with respect to dividend rights and distribution rights upon the liquidation, winding-up or dissolution of the Corporation, shall rank (a) senior to any Junior Securities; (b) on a parity basis with any Parity Securities; and (c) junior to any Senior Equity Securities.


Section 2. Standard Definitions.

As used herein with respect to the Series A Preferred Shares:

Affiliate” means, with respect to any specified Person, any other Person directly or indirectly controlling or controlled by or under direct or indirect common control with such specified Person.

For the purposes of this definition, “control,” when used with respect to any specified Person, means the power to direct or cause the direction of the management and policies of such Person, directly or indirectly, whether through the ownership of voting securities, by contract or otherwise; and the terms “controlling” and “controlled” have meanings correlative to the foregoing.

Board” shall have the meaning set forth in the recitals hereto.

Business Day” means any day other than a day on which federal or state banking institutions in the Borough of Manhattan, The City of New York, are authorized or obligated by law, executive order or regulation to close.

Bylaws” means the Third Amended and Restated Bylaws of the Corporation, as they may be amended or restated from time to time.

Calculation Agent” means, at any time, the Person appointed by the Corporation and serving as such agent with respect to the Series A Preferred Shares at such time. For the avoidance of doubt, the Corporation or any of its subsidiaries or affiliates may act as the Calculation Agent.

Capital Stock” means (a) in the case of a corporation or company, corporate stock or shares, (b) in the case of an association or business entity, any and all shares, interests, participations, rights or other equivalents (however designated) of corporate stock, (c) in the case of a partnership or limited liability company, partnership interests (whether general or limited) or membership interests, and (d) any other interest or participation that confers on a Person the right to receive a share of the profits and losses of, or distributions of assets of, the issuing Person, but excluding from all of the foregoing any debt securities convertible into Capital Stock, whether or not such debt securities include any right of participation with Capital Stock.

Cash Equivalents” means, as at any date of determination, any of the following: (i) marketable securities (a) issued or directly and unconditionally guaranteed as to interest and principal by the United States government or (b) issued by any agency of the United States the obligations of which are backed by the full faith and credit of the United States, in each case maturing within one year after such date; (ii) marketable direct obligations issued by any state of the United States of America or any political subdivision of any such state or any public instrumentality thereof, in each case maturing within one year after such date and having, at the time of the acquisition thereof, a rating of at least A-1 from S&P or at least P-1 from Moody’s; (iii) commercial paper maturing no more than three months from the date of creation thereof and having, at the time of the acquisition thereof, a rating of at least A-1 from S&P or at least P-1 from Moody’s; (iv) certificates of deposit or bankers’ acceptances maturing within three months after such date and issued or accepted by any lender or by any commercial bank organized under the laws of the United States of America or any state thereof or the District of Columbia that (a) is at least “adequately capitalized” (as defined in the regulations of its primary Federal banking regulator) and (b) has Tier 1 capital (as defined in such regulations) of not less than $1,000,000,000; and (v) shares of any money market mutual fund that (a) has substantially all of its assets invested continuously in the types of investments referred to in clauses (i) and (ii) above, (b) has net assets of not less than $5,000,000,000, and (c) has the highest rating obtainable from either S&P or Moody’s.

 

2


Certificate of Designations” shall have the meaning set forth in the recitals hereto.

Certificate of Incorporation” shall have the meaning set forth in the recitals hereto.

Change of Control” means the occurrence, after the Initial Issue Date, of:

(a) the consummation of any transaction (including, without limitation, any merger or consolidation) the result of which is that any “person” or “group” of related persons (as such terms are used in Section 13(d)(3) of the Exchange Act) other than any of the Permitted Holders, becomes the beneficial owner (as such term is defined in Rules 13d-3 and Rule 13d-5 under the Exchange Act), directly or indirectly, of more than 50% of the voting power of the Voting Stock of the Corporation (or its successors by merger, consolidation or purchase of all or substantially all of its assets); or

(b) the direct or indirect sale, lease, transfer, conveyance or other disposition (other than by way of merger or consolidation), in one or a series of related transactions, of all or substantially all of the properties or assets of the Corporation and its Subsidiaries taken as a whole to any “person” (as such term is used in Section 13(d)(3) of the Exchange Act) other than any of the Permitted Holders;

provided, however, that a transaction in which the Corporation becomes a Subsidiary of another Person (other than any of the Permitted Holders) shall not constitute a Change of Control if (a) the stockholders of the Corporation immediately prior to such transaction “beneficially own” (as such term is defined in Rule 13d-3 and Rule 13d-5 under the Exchange Act), directly or indirectly through one or more intermediaries, at least a majority of the voting power of the outstanding Voting Stock of the Corporation immediately following the consummation of such transaction or (b) immediately following the consummation of such transaction, no “person” (as such term is defined above), other than such other Person (but including the holders of the Equity Interests of such other Person) and/or any of the Permitted Holders, “beneficially owns” (as such term is defined above), directly or indirectly through one or more intermediaries, more than 50% of the voting power of the outstanding Voting Stock of the Corporation; provided further, (i) a Person or group shall not be deemed to beneficially own Voting Stock subject to an equity or asset purchase agreement, merger agreement, option agreement, warrant agreement or similar agreement (or voting or option or similar agreement related thereto) until the consummation of the acquisition of Voting Stock in connection with the transactions contemplated by such agreement, (ii) the phrase “person” or “group” is within the meaning of Section 13(d) or 14(d) of the Exchange Act, but excluding (A) any employee benefit plan of such Person or “group” and its subsidiaries and any Person acting in its capacity as trustee, agent or other fiduciary or administrator of any such plan and (B) any underwriter in connection with an IPO, and (iii) if any group includes one or more Permitted Holders, the issued and outstanding Voting Stock of the Corporation or the IPO entity beneficially owned, directly or indirectly, by any Permitted Holders that are part of such group shall not be treated as being beneficially owned by such “group” or any other member of such group for purposes of determining whether a Change of Control has occurred.

 

3


Change of Control Redemption Period” shall have the meaning set forth in Section 5(c).

Change of Control Trigger Event” means the occurrence of both a Change of Control and a Rating Decline.

Clearstream” means Clearstream Banking, société anonyme, Luxembourg.

Close of Business” means 5:00 p.m., New York City time.

Commission” means the U.S. Securities and Exchange Commission.

Common Stock” means the common stock, par value $0.01 per share, of the Corporation.

Controlled Investment Affiliate” means, as to any Person, any other Person, which directly or indirectly is in control of, is controlled by, or is under common control with such Person and is organized by such Person (or any Person controlling such Person) primarily for making direct or indirect equity or debt investments in the Corporation and/or other companies.

Corporation” shall have the meaning set forth in the preamble hereto.

DGCL” shall have the meaning set forth in the preamble hereto.

Dividend Payment Date” means the 30th day of March and September of each year, commencing on March 30, 2025.

Dividend Period” means the period from, and including, a Dividend Payment Date to, but excluding, the next Dividend Payment Date, except that the initial Dividend Period shall commence on, and include, the Initial Issue Date.

Dividend Rate” shall have the meaning set forth in Section 3(a).

DTC” means The Depository Trust Company or any successor thereto.

Eligible Parity Stock” shall have the meaning set forth in Section 8(a).

Equity Interests” means Capital Stock and all warrants, options or other rights to acquire Capital Stock (but excluding any debt security that is convertible into, or exchangeable for, Capital Stock).

Euroclear” means Euroclear Bank S.A./N.V

Exchange Act” means the Securities Exchange Act of 1934, as amended, and the rules and regulations thereunder.

First Reset Date” means September 30, 2029.

 

4


Five-Year U.S. Treasury Rate” means, as of any Reset Dividend Determination Date, the arithmetic mean of the yields on actively traded U.S. Treasury securities adjusted to constant maturity, for five-year maturities, for the most recent five Business Days appearing under the caption “Treasury Constant Maturities” in the most recent H.15. If the Five-Year U.S. Treasury Rate cannot be determined pursuant to the method described above, the Calculation Agent, after consulting such sources as it deems comparable to the foregoing calculation, or any such source as it deems reasonable from which to estimate the Five-Year U.S. Treasury Rate, will determine the Five-Year U.S. Treasury Rate in its sole discretion, provided that if the Calculation Agent determines there is an industry-accepted successor Five-Year U.S. Treasury Rate, then the Calculation Agent will use such successor rate. If the Calculation Agent has determined a substitute or successor base rate in accordance with the foregoing, the Calculation Agent in its sole discretion may determine the business day convention and the Reset Dividend Determination Date to be used and any other relevant methodology for calculating such substitute or successor base rate, including any adjustment factor needed to make such substitute or successor base rate comparable to the Five-Year U.S. Treasury Rate, in a manner that is consistent with industry- accepted practices for such substitute or successor base rate.

GAAP” means (1) generally accepted accounting principles in the United States of America as in effect from time to time; provided, that if any such accounting principle changes after the Initial Issue Date, the Corporation may, at its option, elect to employ such accounting principle or (2) if elected by the Corporation, any accounting principles that are recognized as being generally accepted as set forth above which are in effect from time to time, in each case as in effect on the first date of the period for which the Corporation makes such an election and thereafter as in effect from time to time; provided further, that in each case any such election, once made, shall be irrevocable.

Governmental Authority” means the government of the United States or any other nation, or of any political subdivision thereof, whether state or local, and any agency, authority, instrumentality, regulatory body, court, central bank or other entity exercising executive, legislative, judicial, taxing, regulatory or administrative powers or functions of or pertaining to government.

H.15” means the daily statistical release designated as such, or any successor publication as determined by the Calculation Agent in its sole discretion, published by the Federal Reserve Board; and “most recent H.15” means the H.15 published closest in time but prior to the Close of Business on the applicable Reset Dividend Determination Date.

Holder” means each Person in whose name any Series A Preferred Share is registered, who shall be treated by the Corporation and the Registrar as the absolute owner of such share of the Series A Preferred Shares for the purpose of making payment and for all other purposes.

Immediate Family Members” means, with respect to any individual, such individual’s child, stepchild, grandchild or more remote descendant, parent, stepparent, grandparent, spouse, former spouse, qualified domestic partner, sibling, mother-in-law, father-in-law, son-in-law and daughter-in-law (including adoptive relationships, the estate of such individual and such other individuals above) and any trust, partnership or other bona fide estate-planning vehicle the only beneficiaries of which are any of the foregoing individuals or any private foundation or fund that is controlled by any of the foregoing individuals or any donor-advised fund of which any such individual is the donor.

 

5


Initial Issue Date” means September 30, 2024, the original issue date of the Series A Preferred Shares.

Investors” means (a) the VGP Investor and (b) the Management Investors and (c) other holders of Equity Interests in the Corporation or any Parent Entity on the Initial Issue Date.

IPO” means (a) the issuance by the Corporation or any Parent Entity of common Equity Interests in an underwritten public offering (other than a public offering pursuant to a registration statement on Form S-8 or comparable filing in any other applicable jurisdiction) pursuant to an effective registration statement filed with the Commission or any other comparable Governmental Authority in any other applicable jurisdiction or pursuant to Rule 144A (whether as a primary offering, a secondary public offering or a combination thereof) and (b) any other transaction or series of related transactions (including any acquisition by, or combination or other similar transaction with, a special purpose acquisition company that (i) is an entity organized or existing under the laws of the U.S., any state thereof or the District of Columbia, (ii) prior to the IPO engaged in no material business or activity other than those related to becoming and acting as a special purpose acquisition company and consummating the IPO and (iii) immediately prior to the IPO had no material assets other than cash and Cash Equivalents) that results in any of the common Equity Interests of the Corporation or any Parent Entity being publicly traded on any U.S. national securities exchange or over-the-counter market or any analogous exchange or market.

Junior Securities” means any classes or series of Common Stock and any other equity security of the Corporation other than any equity securities that are Parity Securities or Senior Equity Securities.

Liquidation Dividend Amount” shall have the meaning set forth in Section 7(a).

Liquidation Preference” means, as to the Series A Preferred Shares, $1,000 per share thereof.

Management Investors” means any individual who is a future, current or former officer, director, manager, member, member of management, employee, consultant or independent contractor of the Corporation, any Subsidiary or any Parent Entity who are (directly or indirectly through one or more investment vehicles) holders of Equity Interests in the Corporation and/or any Parent Entity and their Permitted Transferees.

Nonpayment Event” shall have the meaning set forth in Section 8(b).

Offering Memorandum” means the preliminary offering memorandum dated September 26, 2024, as supplemented by the related pricing term sheet dated September 26, 2024, and the final offering memorandum dated September 26, 2024, relating to the initial offering and sale of the Series A Preferred Shares.

Parent Entity” means the Corporation and any Person that is the direct or indirect parent of the Corporation and of which the Corporation is a direct or indirect Subsidiary.

 

6


Parity Securities” means any equity security of the Corporation with terms providing that such equity security ranks on a parity basis with the Series A Preferred Shares with respect to rights to the payment of dividends and/or distributions upon the liquidation, winding-up and dissolution of the Corporation’s affairs, as applicable.

Paying Agent” initially means Equiniti Trust Company, LLC, the Corporation’s duly appointed paying agent for the Series A Preferred Shares, and any successor appointed under Section 9.

Permitted Holder” means (a) the Investors and (b) any Person with which one or more Investors form a “group” (within the meaning of Section 14(d) of the Exchange Act as in effect on the date of the Certificate of Designations) so long as, in the case of this clause (b), such one or more Investors directly or indirectly collectively beneficially own more than 50% of the aggregate voting Equity Interests beneficially owned by the group.

Permitted Parent Payments” means any dividend or distribution to a Parent Entity (i) solely used to fund Permitted Restricted Payments by such Parent Entity that would be permitted if the Series A Preferred Shares were issued by such Parent Entity; (ii) for any taxable period for which the Corporation and/or any of its Subsidiaries are members of a consolidated, combined, unitary or similar group for any U.S. federal, state, local, or non-U.S. income Tax purposes, to pay any U.S. federal, state, local, or non-U.S. income Taxes, or any franchise Taxes imposed in lieu thereof, owed by any parent of any consolidated, combined, unitary or similar group that includes the Corporation and/or any of its Subsidiaries to the extent attributable to the income of the Corporation and/or its Subsidiaries determined as if the Corporation and/or such Subsidiaries filed a consolidated, combined, unitary or similar return separately from any other members of the group (and net of any payments already made to such parent in respect of such Taxes); (iii) to pay such Parent Entity’s general operating and compliance costs and expenses (including operating expenses and other corporate overhead costs and expenses (including payroll, cash management, purchasing, insurance and hedging arrangements, management, technology and licensing arrangements, administrative, legal, audit, accounting, Tax and other reporting and similar costs and expenses)) that are incurred in the ordinary course of business or consistent with past practice or industry norms and are attributable to the ownership or operation of the Corporation and its Subsidiaries; (iv) to pay franchise, excise and similar Taxes, and other fees, Taxes and expenses, required to maintain such Parent Entity’s organizational existence; and (v) to pay salary, bonus, long-term incentive, indemnity, severance and other benefits, including payments to service providers of the Corporation and its Subsidiaries pursuant to any incentive plan (whether in the form of options, cash settled options or otherwise), as well as applicable employment, social security or similar Taxes, in each case to the extent such salary, bonuses, incentives, indemnities, severance or other benefits are incurred in the ordinary course of business or consistent with past practice or industry norms and are attributable to the ownership or operation of the Corporation and its Subsidiaries.

Permitted Transferees” means, with respect to any Person that is a natural Person (and any Permitted Transferee of such Person), (a) such Person’s Immediate Family Members and (b) such Person’s estate, heirs, legatees, distributees, executors and/or administrators upon the death of such Person, or any private foundation or fund that is controlled thereby, and any other Person who was an Affiliate of such Person upon the death of such Person and who, upon such death, directly or indirectly owned Equity Interests in the Corporation or any Parent Entity.

 

7


Person” means any individual, corporation, limited liability company, partnership, joint venture, association, joint-stock company, trust, unincorporated organization or other business entity or any government or any agency or political subdivision thereof.

Preferred Stock” shall have the meaning set forth in the recitals hereto.

Preferred Stock Directors” shall have the meaning set forth in Section 8(b).

Rating Agency” means any of the following: (a) S&P Global Ratings, a division of S&P Global Inc. (“S&P”); (b) Moody’s Investors Service, Inc. (“Moody’s”); or (c) Fitch Ratings, Inc. (“Fitch”), and, in each case, their respective successors.

Rating Decline” means, in connection with any Change of Control, the occurrence of:

(1) during the occurrence and continuance of any period in which the Series A Preferred Shares have two or more (or, if only one of the following ratings agencies is at the applicable time providing a rating for the Series A Preferred Shares, one) ratings equal to or greater than (x) Baa3 by Moody’s, (y) BBB- by S&P and (z) BBB- by Fitch (or, if all of such entities cease to provide such ratings, the equivalent rating from any other “nationally recognized statistical rating organization” registered with the Commission) (such period, an “Investment Grade Period”), a ratings downgrade which results in the Series A Preferred Shares no longer having two (or, if only one of the preceding ratings agencies is at the time providing a rating for the Series A Preferred Shares, one) such ratings of at least BBB- or Baa3, as applicable; or

(2) during any period which is not an Investment Grade Period, a ratings downgrade of the Series A Preferred Shares by any two (or, if only one of the following ratings agencies is at the time providing a rating for the Series A Preferred Shares, one) of (x) Moody’s, (y) S&P and (z) Fitch (or, if all of such entities cease to provide such ratings, the equivalent rating from any other “nationally recognized statistical rating organization” registered with the Commission);

provided, however, that in each case such downgrade occurs on, or within 90 days after the earlier of (a) such Change of Control, (b) the date of public notice of the occurrence of such Change of Control, or (c) public notice of the intention by the Corporation to effect such Change of Control (which period shall be extended so long as the rating of the Corporation is under publicly announced consideration for downgrade by any Rating Agency); and provided further, that a Rating Decline otherwise arising by virtue of a particular reduction in rating will not be deemed to have occurred in respect of a particular Change of Control (and thus will be disregarded in determining whether a Rating Decline has occurred for purposes of the definition of Change of Control Trigger Event) if the Rating Agencies making the reduction in rating do not announce or publicly confirm or inform the Corporation that the reduction was the result, in whole or in part, of any event or circumstance comprised of or arising as a result of, or in respect of, the applicable Change of Control (whether or not the applicable Change of Control has occurred at the time of the Rating Decline); and provided further, that no Change of Control Trigger Event shall occur if following any downgrade which would otherwise result in a Change of Control Trigger Event, the ratings of the Series A Preferred Shares by at least two of the rating agencies are equal to or better than their respective ratings on the Initial Issue Date.

 

8


Rating Event” means a change by any Rating Agency to its Equity Credit criteria for securities such as the Series A Preferred Shares, as such criteria are in effect as of the Initial Issue Date (the “Current Criteria”), which change results in (i) any shortening of the length of time for which the Current Criteria are scheduled to be in effect with respect to the Series A Preferred Shares or (ii) a lower Equity Credit being given to the Series A Preferred Shares than the Equity Credit that would have been assigned to the Series A Preferred Shares by such Rating Agency pursuant to the Current Criteria. “Equity Credit” for the purposes of the Series A Preferred Shares means the dollar amount or percentage in relation to the Liquidation Preference per Series A Preferred Share assigned to the Series A Preferred Shares as equity, rather than debt, by a Rating Agency in evaluating the capital structure of an entity.

Record Date” means, with respect to any Dividend Payment Date, the Close of Business on the 15th day of the month of the applicable Dividend Payment Date, except that in the case of payments of dividends in arrears, the record date with respect to a Dividend Payment Date will be such date as may be designated by the Board in accordance with the Corporation’s Certificate of Incorporation and Bylaws.

Record Holder” means, (i) with respect to any Dividend Payment Date, a Holder of record of the Series A Preferred Shares as such Holder appears on the stock register of the Corporation at the Close of Business on the related Record Date, (ii) with respect to any redemption of Series A Preferred Shares by the Corporation pursuant to the provisions of Section 5 and the procedures for any such redemption pursuant to the provisions of Section 6, a Holder of record of the Series A Preferred Shares as such Holder appears on the stock register of the Corporation at the time notice of redemption is given and (iii) with respect to voting rights of the Series A Preferred Shares pursuant to the provisions of Section 8, a Holder of record of the Series A Preferred Shares as such Holder appears on the stock register of the Corporation at the Close of Business on the record date fixed in accordance with Section 8(e).

Redemption Date” means any date fixed for redemption of any Series A Preferred Shares pursuant to the provisions of Section 5, as such date may be delayed pursuant to Section 6.

Registrar” initially means Equiniti Trust Company, LLC, the Corporation’s duly appointed registrar for the Series A Preferred Shares, and any successor appointed under Section 8.

Reset Date” means the First Reset Date and each date falling on the fifth anniversary of the preceding Reset Date.

Reset Dividend Determination Date” means, in respect of any Reset Period, the day falling two Business Days prior to the beginning of such Reset Period.

Reset Period” means the period from and including the First Reset Date to, but excluding, the next following Reset Date and thereafter each period from and including each Reset Date to, but excluding, the next following Reset Date.

 

9


Securities Depositary” means DTC or any successor thereto.

Senior Equity Securities” means any equity security of the Corporation issued after the Initial Issue Date with terms specifically providing that such equity security ranks senior to the Series A Preferred Shares with respect to rights to the payment of dividends and/or distributions upon the liquidation, winding-up and dissolution of the Corporation’s affairs, as applicable.

Series A Preferred Shares” shall have the meaning set forth in the recitals hereto.

Subsidiary” means, with respect to any specified Person:

(1) any corporation, association or other business entity of which more than 50% of the total voting power of shares of Capital Stock entitled (without regard to the occurrence of any contingency and after giving effect to any voting agreement or stockholders’ agreement that effectively transfers voting power) to vote in the election of directors, managers or trustees of the corporation, association or other business entity is at the time owned or controlled, directly or indirectly, by that Person or one or more of the other Subsidiaries of that Person (or a combination thereof);

(2) any partnership, joint venture, limited liability company or similar entity of which: more than 50% of the capital accounts, distribution rights, total equity and voting interests or general or limited partnership interests, as applicable, are owned or controlled, directly or indirectly, by such Person or one or more of the other Subsidiaries of that Person (or a combination thereof) whether in the form of membership, general, special or limited partnership or otherwise, and such Person or any Subsidiary of such Person is a controlling general partner or otherwise controls such entity; and

(3) any other entity, the management of which is controlled, directly or indirectly (whether by way of equity ownership or contractual arrangements or otherwise), by that Person or one or more of the other Subsidiaries of that Person (or a combination thereof) and the accounts of which would be consolidated with those of such Person in its consolidated financial statements as of such date prepared in accordance with GAAP.

Unless otherwise specified herein, a “Subsidiary” shall refer to a Subsidiary of the Corporation.

Tax” means all present or future taxes, levies, imposts, duties, assessments, charges, fees, deductions or withholdings (together with interest, penalties and other additions thereto) of any nature and whatever called, by whomsoever, on whomsoever and wherever imposed, levied, collected, withheld or assessed.

Transfer Agent” shall initially mean Equiniti Trust Company, LLC, the Corporation’s duly appointed transfer agent for the Series A Preferred Shares, and any successor appointed under Section 8.

VGP Investor” means, collectively, (a) Venture Global Partners II, LLC and its Affiliates and (b) the funds, partnerships or other co-investment vehicles managed, advised or controlled by any Person referred to in the foregoing clause (a).

 

10


Voting Stock” of any specified Person as of any date means the Capital Stock of such Person that is at that time entitled to vote generally in the election of the board of directors (or comparable governing body) of such Person, measured by voting power rather than number of shares. For the avoidance of doubt, the sole managing member of a sole-member-managed limited liability company owns 100% of the Voting Stock of such limited liability company and the sole general partner of a limited partnership owns 100% of the Voting Stock of the limited partnership.

Section 3. Dividends.

(a) Subject to the rights of holders of any Senior Equity Security of the Corporation ranking senior to the Series A Preferred Shares with respect to dividends, Holders shall be entitled to receive, when, as and if declared by the Board, or an authorized committee thereof, out of legally available funds of the Corporation for such purpose, semi-annual cash dividends. Dividends on the Series A Preferred Shares will be cumulative from the Initial Issue Date and will be payable semi-annually in arrears on each Dividend Payment Date at the Dividend Rate. Declared dividends shall be payable no later than Close of Business on the relevant Dividend Payment Date to Record Holders on the applicable Record Date. If a Dividend Payment Date is not a Business Day, payment shall be made on the immediately succeeding Business Day, without the accumulation of additional dividends. The Dividend Rate on the Series A Preferred Shares from, and including, the Initial Issue Date to, but excluding, the First Reset Date shall be 9.00% per annum of the Liquidation Preference. On and after the First Reset Date, the Dividend Rate on the Series A Preferred Shares for each Reset Period will be a per annum rate of the Liquidation Preference equal to the Five-Year U.S. Treasury Rate as of the most recent Reset Dividend Determination Date plus a spread of 5.44% per annum; provided that the Five-Year U.S. Treasury Rate for each Reset Period will not be lower than 1.00%. “Dividend Rate” means the dividend rate on the Series A Preferred Shares from time to time, as determined pursuant to this paragraph.

(b) The Dividend Rate for each Reset Period shall be determined by the Calculation Agent as of the applicable Reset Dividend Determination Date in accordance with the terms set forth in this Section 3. Promptly upon such determination, the Calculation Agent shall notify the Corporation of the applicable Dividend Rate and amount of dividends for the Reset Period. The Calculation Agent’s determination of any Dividend Rate, and its calculation of the amount of dividends for any Dividend Period beginning on or after the First Reset Date shall be on file at the Corporation’s principal office, shall be made available to any Record Holder upon request and shall be final and binding in the absence of manifest error. The Corporation shall give notice of the relevant Five-Year U.S. Treasury Rate as soon as reasonably practicable following the determination thereof to the Transfer Agent and Registrar for the Series A Preferred Shares.

(c) Any dividend payable on the Series A Preferred Shares for any Dividend Period, including for any partial Dividend Period, shall be computed on the basis of a 360-day year consisting of twelve 30-day months. Dividends will accumulate in each such Dividend Period from, and including, the preceding Dividend Payment Date or the Initial Issue Date, as the case may be, to, but excluding, the applicable Dividend Payment Date for such Dividend Period. If any Dividend Payment Date otherwise would fall on a day that is not a Business Day, declared dividends will be paid on the immediately succeeding Business Day without the accumulation of additional dividends or interest.

 

11


(d) Dividends on the Series A Preferred Shares will accumulate whether or not (i) the Corporation has earnings, (ii) there are funds legally available for the payment of such dividends, (iii) the payment of such dividends is then permitted under Delaware or other applicable law, (iv) such dividends are authorized or declared by the Board, and (v) any agreements to which the Corporation is a party (including any agreements relating to the Corporation’s indebtedness) prohibit the payment of dividends. Holders of Series A Preferred Shares will not be entitled to any dividend, whether payable in cash, property or securities, in excess of full cumulative dividends. No additional dividends, interest or sum of money in lieu of interest will be payable in respect of any dividend payment which may be in arrears on the Series A Preferred Shares. Unless full cumulative dividends have been or contemporaneously are being paid or declared and a sum sufficient for the payment thereof set apart for payment on all outstanding Series A Preferred Shares with respect to dividends through the most recent Dividend Payment Date on which dividends were to be paid in accordance with the terms of this Certificate of Designations, (i) no dividend or distribution may be declared or paid or set apart for payment on any Junior Securities (other than a dividend or distribution payable solely in Junior Securities and the liquidation, winding-up and dissolution of the Corporation’s affairs), including Common Stock, and (ii) the Corporation may not redeem, purchase or otherwise acquire any Parity Securities or Junior Securities, including Common Stock, in each case, subject to the following exceptions: (A) any dividend or distribution payable in shares of Common Stock or other Junior Securities, together with cash in lieu of any fractional share; (B) the acquisition of (i) Series A Preferred Shares or any Parity Securities in exchange for other Parity Securities (with the same or lesser aggregate liquidation amount), Common Stock or other Junior Securities or (ii) shares of Common Stock or other Junior Securities in exchange for shares of Common Stock or other Junior Securities, in each case, together with cash in lieu of any fractional share; (C) (i) payments made or expected to be made (including repurchases of Capital Stock) in respect of withholding or similar Taxes payable in connection with the exercise or vesting of Capital Stock or any other equity award by any future, present or former employee, director, officer, manager, contractor, consultant or advisor (or their respective Controlled Investment Affiliates or Immediate Family Members) of the Corporation or any of its Subsidiaries or any Parent Entity, or (ii) purchases, repurchases, redemptions, defeasances or other acquisitions or retirements of Capital Stock in connection with any equity subscription agreement, stock option agreement, restricted stock grant, stockholders’ agreement, employee benefit or other incentive plan, including any employment contract, or similar agreement, including, without limitation, the forfeiture of unvested shares of restricted stock or share withholdings or other surrender of shares to which the holder may otherwise be entitled, or that are deemed to occur, upon the exercise, conversion or exchange of stock options, warrants, equity-based awards or other rights in respect thereof if such Capital Stock represents a portion of the exercise price thereof or payments in respect of withholding or similar Taxes payable upon exercise or vesting thereof; (D) purchases of fractional interests in shares of Capital Stock, including payment of cash in lieu of the issuance thereof, (i) arising out of stock dividends, splits or combinations or business combinations and payments or distributions to dissenting stockholders pursuant to applicable law in connection with a consolidation, merger or transfer of assets or (ii) upon the exercise of options, warrants or similar securities or the conversion or exchange of Capital Stock; (E) purchases of Common Stock or other Junior Securities pursuant to a contractually binding requirement to buy Common Stock or other Junior Securities existing prior to the immediately preceding Dividend Period, including under a contractually binding stock repurchase plan; (F) the exchange or conversion of Junior Securities for or into other Junior Securities or of

 

12


Parity Securities for or into other Parity Securities (with the same or lesser aggregate liquidation amount) or Junior Securities and, in each case, the payment of cash in lieu of fractional shares; (G) any dividends or distributions of rights in connection with a stockholders’ rights plan or any redemption or repurchase of rights pursuant to any stockholders’ rights plan; (H) any payments by the Corporation and its Subsidiaries pursuant to any Tax sharing agreements or other equity agreements in respect of Taxes among the Corporation, its Subsidiaries and/or any Parent Entity, in each case incurred in the ordinary course of business or consistent with past practice or industry norms and that are attributable to the ownership or operation of the Corporation and its Subsidiaries; (I) payments made in connection with or relating to any transactions effected in connection with and reasonably related to consummating an IPO or any reorganizations and other activities related to Tax planning and Tax reorganization; (J) payments in connection with any administrative services agreement, operations and maintenance agreement, marketing agreement, charter agreement, shipping agency agreement, reciprocal services agreement, excess capacity offtake agreement (including any sale and purchase agreement entered into in connection therewith) or other similar agreement or arrangement with the VGP Investor or any of its Affiliates, in each case entered into in the ordinary course of business or consistent with past practice or industry norms, or that are on terms, taken as a whole, which are fair to the Corporation or any applicable Subsidiary of the Corporation or at least as favorable to the Corporation or such Subsidiary of the Corporation as might reasonably have been obtained at such time from an unaffiliated party in each case as determined by the Corporation in good faith; (K) payments (including any payment to any Parent Entity for further payment by such Parent Entity) (i) to reimburse the VGP Investor and any of its Affiliates and designees for any reasonable or customary out-of-pocket costs and expenses incurred in connection with the provision of any management, advisory, consulting or other similar services, and (ii) to pay reasonable or customary management, monitoring, consulting and similar fees to the VGP Investor (with respect to (A) through (K)) of the foregoing, collectively, the “Permitted Restricted Payments”); and (L) any Permitted Parent Payments. Accumulated dividends in arrears for any past Dividend Period may be declared by the Board, or an authorized committee thereof, and paid on any date fixed by the Board, whether or not a Dividend Payment Date, to Holders of the Series A Preferred Shares on the Record Date for such payment, which may not be less than 10 days before the payment date of such dividend. To the extent a Dividend Period applicable to a class of Junior Securities or Parity Securities is shorter than the Dividend Period applicable to the Series A Preferred Shares (e.g., quarterly rather than semi-annually), the Board may declare and pay regular dividends with respect to such Junior Securities or Parity Securities so long as, at the time of declaration of such dividend, the Board expects the Corporation will have sufficient funds to pay the full dividend in respect of the Series A Preferred Shares on the next Dividend Payment Date.

(e) Subject to the next succeeding sentence, if all accumulated dividends in arrears on all outstanding Series A Preferred Shares and any Parity Securities have not been declared and paid, or sufficient funds for the payment thereof have not been set apart, payment of accumulated dividends in arrears will be made in order of the dates on which such dividends were to be made in accordance with the terms of such securities (for the Series A Preferred Shares, the relevant Dividend Payment Dates), commencing with the earliest such payment date. If less than all dividends payable with respect to all Series A Preferred Shares and any Parity Securities are paid, any partial payment will be made pro rata with respect to the Series A Preferred Shares and any Parity Securities entitled to a dividend payment at such time in proportion to the aggregate amounts remaining due in respect of such Series A Preferred Shares and Parity Securities at such time.

 

13


(f) So long as the Series A Preferred Shares are held of record by the nominee of the Securities Depositary, the dividends will be paid by the Paying Agent to the Securities Depositary in same-day funds on each Dividend Payment Date.

Section 4. Calculation Agent.

Unless the Corporation has validly called all of the Series A Preferred Shares for redemption on the First Reset Date, the Corporation will appoint the Calculation Agent for the Series A Preferred Shares prior to the Reset Dividend Determination Date preceding the First Reset Date and will keep a record of such appointment at the Corporation’s principal office, which will be available to any Record Holder of Series A Preferred Shares upon request. The Corporation may appoint, at any time and from time to time, any person or entity (including the Corporation or any of its Subsidiaries or Affiliates) to serve as the Calculation Agent. The Corporation may terminate any such appointment and may appoint a successor Calculation Agent at any time and from time to time.

Section 5. Optional Redemption by the Corporation.

(a) Optional Redemption After the First Reset Date. At any time on or after the First Reset Date, the Corporation may, at its option, redeem, in whole or in part, on one or more occasions, the Series A Preferred Shares at a redemption price payable in cash of $1,000 (100% of the Liquidation Preference) per Series A Preferred Share plus an amount equal to all accumulated and unpaid dividends thereon to, but excluding, the Redemption Date, whether or not declared. The Corporation may undertake multiple partial redemptions. For the avoidance of doubt, the Corporation shall have the right (but not the obligation) to redeem the Series A Preferred Shares as set forth in this Section 5(a) at any time on or after the First Reset Date notwithstanding the occurrence of any other event(s) that would give rise to the Corporation having an option to redeem the Series A Preferred Shares at the applicable redemption price(s) specified herein for such event(s).

(b) Optional Redemption Upon a Rating Event. At any time within 120 days after the conclusion of any review or appeal process instituted by the Corporation following the occurrence of a Rating Event, the Corporation may, at its option, redeem the Series A Preferred Shares in whole, but not in part, at a redemption price payable in cash of $1,020 per share (102% of the Liquidation Preference) per Series A Preferred Share plus an amount equal to all accumulated and unpaid dividends thereon to, but excluding, the Redemption Date, whether or not declared.

(c) Optional Redemption Upon Change of Control Trigger Event. At any time within 120 days after the first date on which a Change of Control Trigger Event occurs (the “Change of Control Redemption Period”), the Corporation may, at its option, redeem, in whole or in part, on one or more occasions, the Series A Preferred Shares at a redemption price payable in cash of $1,030 (103.00% of the Liquidation Preference) per share for a Change of Control Trigger Event that occurs before September 30, 2025, $1,020 (102.00% of the Liquidation Preference) per share for a Change of Control Trigger Event that occurs on or after September 30, 2025 and before September 30, 2026 or $1,010 (101.00% of the Liquidation Preference) per share for a Change of Control Trigger Event that occurs on or after September 30, 2026 and before September 30, 2029, plus an amount equal to all accumulated and unpaid dividends thereon to, but excluding, the

 

14


Redemption Date, whether or not declared. The Corporation may undertake multiple partial redemptions. If the Corporation does not exercise its option to redeem all Series A Preferred Shares within the Change of Control Redemption Period, then the then-applicable Dividend Rate for the Series A Preferred Shares not so redeemed will be increased by 5.00% with effect from the first day after such Change of Control Redemption Period.

(d) Any optional redemption would be effected only out of funds legally available for such purpose and subject to compliance with the provisions of the instruments governing the Corporation’s outstanding indebtedness.

Section 6. Procedures for Optional Redemption by the Corporation.

If the Series A Preferred Shares are to be redeemed pursuant to Section 5 hereof, the notice of redemption shall be given by first class mail, postage prepaid, electronically, or pursuant to the procedures of the Securities Depository, to the Record Holders of the Series A Preferred Shares to be redeemed as such Record Holders’ names appear on the stock transfer books maintained by the Registrar and Transfer Agent at the address of such Record Holders shown therein, given not less than 10 days, nor more than 60 days, prior to the scheduled Redemption Date. Such notice, in the Corporation’s discretion, may provide that such redemption is subject to the satisfaction of one or more conditions precedent, in which case the notice shall state that, in the Corporation’s discretion, the Redemption Date may be delayed until such time as any or all conditions shall be satisfied or waived, or such redemption may not occur and such notice may be rescinded in the event that any or all such conditions shall not have been satisfied or waived by the Redemption Date, or by the Redemption Date as so delayed. In addition, the Corporation may provide in such notice that payment of the redemption price and performance of the Corporation’s obligations with respect to such redemption may be performed by another Person it being understood that any such provision for payment by another Person will not relieve the Corporation from its obligations with respect to such redemption. Each notice of redemption shall include a statement setting forth:

(a) the Redemption Date and basis under which such Series A Preferred Shares are being redeemed;

(b) the total number of Series A Preferred Shares to be redeemed and, if less than all the outstanding shares of Series A Preferred Shares are to be redeemed, the number (and in the case of Series A Preferred Shares in certificated form, the identification) of the Series A Preferred Shares to be redeemed;

(c) the redemption price;

(d) the place where any Series A Preferred Shares in certificated form are to be redeemed and shall be presented and surrendered for payment of the redemption price therefor;

(e) that dividends on the Series A Preferred Shares to be redeemed will cease to accumulate from and after such Redemption Date; and

(f) if such redemption is being made in connection with a Change of Control Trigger Event, a brief description of the transaction or transactions constituting such Change of Control Trigger Event.

 

15


If fewer than all of the outstanding Series A Preferred Shares are to be redeemed, the number of Series A Preferred Shares to be redeemed will be determined by the Corporation, and such shares will be redeemed by such method of selection as the Securities Depositary shall determine, pro rata or by lot, with adjustments to avoid redemption of fractional units. So long as all Series A Preferred Shares are held of record by the nominee of the Securities Depositary, the Corporation will give notice, or cause notice to be given, to the Securities Depositary of the number of Series A Preferred Shares to be redeemed, and the Securities Depositary will determine the number of Series A Preferred Shares to be redeemed from the account of each of its participants holding Series A Preferred Shares in its participant account. Thereafter, each participant will select the number of Series A Preferred Shares to be redeemed from each beneficial owner for whom it acts (including the participant, to the extent it holds Series A Preferred Shares for its own account). A participant may determine to redeem Series A Preferred Shares from some beneficial owners (including the participant itself) without redeeming Series A Preferred Shares from the accounts of other beneficial owners.

So long as the Series A Preferred Shares are held of record by the nominee of the Securities Depositary, the redemption price will be paid by the Paying Agent to the Securities Depositary on the Redemption Date.

If the Corporation gives or causes to be given a notice of redemption, then the Corporation will deposit with the Paying Agent funds sufficient to redeem the Series A Preferred Shares as to which notice has been given on the Redemption Date (subject to the satisfaction or waiver of all conditions), and will give the Paying Agent irrevocable instructions and authority to pay the redemption price to the Holder or Holders thereof upon surrender or deemed surrender of the certificates therefor (which will occur automatically if the certificate representing such Series A Preferred Shares is issued in the name of the Securities Depositary or its nominee). If a notice of redemption shall have been given, then from and after the Redemption Date, unless the Corporation defaults in providing funds sufficient for such redemption at the time and place specified for payment pursuant to the notice, all dividends on such Series A Preferred Shares will cease to accumulate and all rights of Holders of such Series A Preferred Shares as stockholders will cease, except the right to receive the redemption price, including an amount equal to accumulated and unpaid dividends to, but excluding, the Redemption Date, whether or not declared. The Holders of Series A Preferred Shares will have no claim to the interest income, if any, earned on such funds deposited with the Paying Agent. Any funds deposited with the Paying Agent hereunder by the Corporation for any reason, including, but not limited to, redemption of Series A Preferred Shares, that remain unclaimed or unpaid after one year after the applicable Redemption Date or other payment date, shall be, to the extent permitted by law, repaid to the Corporation upon the Corporation’s written request, after which repayment the Holders of the Series A Preferred Shares entitled to such redemption or other payment shall have recourse only to the Corporation.

If only a portion of the Series A Preferred Shares represented by a certificate has been called for redemption, upon surrender of the certificate to the Paying Agent (which will occur automatically if the certificate representing such Series A Preferred Shares is registered in the name of the Securities Depositary or its nominee), the Corporation will issue and the Paying Agent will deliver to the Holder of such Series A Preferred Shares a new certificate representing the number of Series A Preferred Shares represented by the surrendered certificate that have not been called for redemption.

 

16


Notwithstanding any notice of redemption, there will be no redemption of any Series A Preferred Shares called for redemption until funds sufficient to pay the full redemption price of such shares, including all accumulated and unpaid dividends to, but excluding, the Redemption Date, whether or not declared, have been deposited by the Corporation with the Paying Agent.

The Corporation may from time to time purchase Series A Preferred Shares, subject to compliance with all applicable securities and other laws. Any Series A Preferred Shares that the Corporation redeems or otherwise acquires will be cancelled.

Notwithstanding the foregoing, in the event that full cumulative dividends on the Series A Preferred Shares have not been paid or declared and set apart for payment, the Corporation may not repurchase, redeem or otherwise acquire, in whole or in part, any Series A Preferred Shares except pursuant to a purchase or exchange offer made on the same relative terms to all Holders of Series A Preferred Shares that are then in arrears.

Section 7. Liquidation, Dissolution or Winding-Up.

(a) In the event of any voluntary or involuntary liquidation, winding-up or dissolution of the Corporation, subject to the preferential rights of Senior Equity Securities with respect to such distribution, the Holders will be entitled to receive out of the assets the Corporation has legally available for distribution to its stockholders the Liquidation Preference per Series A Preferred Share, plus an amount (the “Liquidation Dividend Amount”) equal to any accumulated and unpaid dividends (whether or not declared) on such shares to, but excluding, the date of payment, before any distribution of assets upon such liquidation, winding-up or dissolution is made to the holders of any Junior Securities with respect to such distribution.

(b) In the event that, upon the voluntary or involuntary liquidation, winding-up or dissolution of the Corporation, the available assets of the Corporation are insufficient to pay the amounts payable with respect to the Liquidation Preference plus the Liquidation Dividend Amount on the shares of Series A Preferred Shares and the corresponding amounts payable on all Parity Securities in the distribution of assets, then the Holders and all holders of any such other Parity Securities will share ratably in any distribution of the Corporation’s assets in proportion to the full liquidating distributions to which they would otherwise be respectively entitled.

(c) The Corporation shall provide the Holders written notice of any such payment upon the Corporation’s voluntary or involuntary liquidation, winding-up or dissolution no fewer than 30 days and no more than 60 days prior to the payment date. After payment to any Holder of the full amount of the Liquidation Preference and the Liquidation Dividend Amount to which such Holder is entitled, such Holder will have no right or claim to any of the remaining assets of the Corporation.

(d) The consolidation, conversion or merger of the Corporation with or into any other entity or of any other entity with or into the Corporation (including any merger or conversion in which the Corporation is not the surviving entity), or the sale, lease, transfer or conveyance of all or substantially all of the Corporation’s property or business, will not be deemed to constitute a liquidation, winding-up or dissolution of the Corporation (although such events may give rise to the optional redemption rights described in Section 5).

 

17


Section 8. Voting Rights.

(a) General. Holders shall not have any voting rights except as set forth in this Section 8 and as otherwise from time to time specifically required by Delaware law. In addition, notwithstanding anything herein to the contrary, Holders shall not have any voting rights, except as otherwise specifically required by Delaware law, following such time as all outstanding Series A Preferred Shares have been redeemed or called for redemption upon proper notice and sufficient funds have been deposited in trust to effect such redemption. On any matter on which Holders are entitled to vote, such Holders will be entitled to one vote per Series A Preferred Share; provided that for any matter on which Holders are entitled to vote with the holders of any Parity Securities upon which like voting rights have been conferred and are exercisable due to the satisfaction of applicable conditions in such Parity Securities with respect to such matter (“Eligible Parity Stock”), voting together as a single class, the Holders and the holders of such Eligible Parity Stock will be entitled to cast one vote for each $25.00 of liquidation preference (in the case of the Series A Preferred Shares, the Liquidation Preference) (excluding accrued and unpaid dividends). Notwithstanding the foregoing, the Series A Preferred Shares held by the Corporation or any of its subsidiaries or controlled Affiliates will not be entitled to vote.

(b) Right to Elect Two Directors Upon Nonpayment.

(i) Whenever any dividends on any Series A Preferred Shares are in arrears for three or more consecutive semi-annual Dividend Periods (a “Nonpayment Event”), the Corporation shall promptly increase the number of directors constituting the Board by two, and the Holders and holders of any Eligible Parity Stock, voting together as a single class, shall be entitled to elect those two additional members of the Board (the “Preferred Stock Directors”). For the avoidance of doubt, in no event shall the total number of Preferred Stock Directors exceed two. The election of the initial Preferred Stock Directors following any Nonpayment Event will occur at a special meeting called by the Corporation at the request of the Record Holders and the holders of record of shares of Eligible Parity Stock collectively representing at least 25% of the aggregate liquidation preference (excluding accrued and unpaid dividends) of all outstanding Series A Preferred Shares and shares of Eligible Parity Stock; provided that, if such a request is received less than 90 days before the date fixed for the next annual or special meeting of the Corporation’s stockholders, if any, then such vote will be held at the earlier of such next annual or special meeting of the Corporation’s stockholders to the extent permitted by the Bylaws. If a special meeting is not called by the Corporation in accordance with the foregoing within 30 days after request from the Holders and holders of shares of Eligible Parity Stock in accordance with the foregoing, then the Record Holders and holders of record of shares of Eligible Parity Stock collectively representing at least 25% of the aggregate liquidation preference (excluding accrued and unpaid dividends) of all outstanding Series A Preferred Shares and shares of Eligible Parity Stock may designate a holder to call the meeting at the Corporation’s expense and, for such purpose and no other (unless provided otherwise by applicable law), such holder of Series A Preferred Shares or shares of Eligible Parity Stock shall have access to the Corporation’s stock ledger. Following the election of the initial Preferred Stock Directors, the Preferred Stock Directors will be subject to election or re-election at each subsequent annual meeting of the Corporation’s stockholders.

 

18


(ii) At each meeting at which the Holders and holders of Eligible Parity Stock are entitled to vote for the election of Preferred Stock Directors, the Record Holders and holders of record of shares of Eligible Parity Stock collectively representing at least a majority of the votes entitled to be cast in respect of such matter, present in person or represented by proxy, will constitute a quorum for the transaction of business.

(iii) Each Preferred Stock Director will be elected by a plurality of the votes cast at such meeting with respect to the election of directors; provided that in no event may any Preferred Stock Director be nominated or elected if the election of such director would cause the Corporation to violate any applicable corporate governance requirements of any exchange or automated quotation system on which the securities of the Corporation or any Parent Entity may then be listed or quoted relating to the independence of directors.

(iv) Any Preferred Stock Director may be removed at any time, with or without cause, by the Record Holders and holders of record of shares of Eligible Parity Stock collectively representing at least a majority of the votes that would be entitled to vote in the election of a Preferred Stock Director.

(v) In the event that a Nonpayment Event shall have occurred and shall not have been remedied, any vacancy in the office of a Preferred Stock Director following the initial election of Preferred Stock Directors may be filled by the vote or consent of the Preferred Stock Director remaining in office or, if none remains in office, by the vote or consent of the Record Holders and holders of record of shares of Eligible Parity Stock collectively representing at least a majority of the votes that would be entitled to vote in the election of a Preferred Stock Director; provided that in no event may any such Preferred Stock Director be appointed if the appointment of such director would cause the Corporation to violate any applicable corporate governance requirements of any exchange or automated quotation system on which the securities of the Corporation or any Parent Entity may then be listed or quoted relating to the independence of directors. Any such appointed Preferred Stock Director will serve until the earlier of his or her resignation, removal or death or the election of his or her successor at the next applicable annual or special meeting of stockholders.

(vi) Following a Nonpayment Event, if and when all accrued dividends on the Series A Preferred Shares for all past Dividend Periods shall have been fully paid (or declared and a sum sufficient for such payment shall have been set aside), the right of Holders to participate in the election of Preferred Stock Directors will cease (subject to the revesting of such right upon any subsequent Nonpayment Event) and, if any Preferred Stock Directors have been elected (unless there are outstanding shares of Eligible Parity Stock in respect of which such voting rights have been conferred and are then still exercisable), the term of office of any Preferred Stock Directors will immediately terminate, the Preferred Stock Directors shall automatically cease to be on the Board without any further action by the Corporation or the Preferred Stock Directors, and the number of directors constituting the Board shall be reduced accordingly.

 

19


(c) Other Voting Rights.

(i) So long as any of the Series A Preferred Shares are outstanding, unless the Corporation has received the affirmative approval, given in person or by proxy, either by consent without a meeting or by vote at an annual or special meeting of such stockholders, of the Holders of a majority of the voting power of the outstanding Series A Preferred Shares, voting as a separate class, the Corporation may not adopt any amendment to its Certificate of Incorporation (including this Certificate of Designations) that would have a material adverse effect on the powers, preferences, duties, or special rights of the Series A Preferred Shares; provided that, to the fullest extent permitted by law, no amendment relating to the authorization, creation or issuance of any class or series of capital stock, or an increase of the authorized amount or an increase or decrease of the par value of the shares thereof, will be deemed to materially adversely affect the terms of the Series A Preferred Shares. Unless required by law, holders of Series A Preferred Shares shall have no voting rights in connection with or relating to a merger, conversion or consolidation between the Corporation and any other entity.

(ii) In addition, so long as any of the Series A Preferred Shares are outstanding, unless the Corporation has received the affirmative approval, given in person or by proxy, either by consent without a meeting or by vote at an annual or special meeting of such stockholders, of the Holders and holders of a majority of the voting power of the outstanding Series A Preferred Shares and the outstanding shares of Eligible Parity Stock entitled to vote thereon, voting together as a class, the Corporation may not:

(A) create or issue any Parity Securities (including any additional Series A Preferred Shares) if the cumulative dividends payable on the outstanding Series A Preferred Shares (or Parity Securities, if applicable) are in arrears; or

(B) create or issue any Senior Equity Securities.

(d) For the avoidance of doubt, notwithstanding the foregoing, the Corporation may amend, alter, supplement, or repeal any terms of the Series A Preferred Shares, including by way of amendment to this Certificate of Designations, without the consent or vote of the Holders (to the fullest extent permitted by applicable law and so long as such action does not materially adversely affect the special rights, preferences, privileges, or voting powers of the Series A Preferred Shares, and limitations and restrictions thereof), for the following purposes:

(i) to cure any ambiguity or mistake, or to correct or supplement any provision contained in this Certificate of Designations establishing the terms of the Series A Preferred Shares that may be defective or inconsistent with any other provision contained in this Certificate of Designations;

(ii) to make conforming changes to any provision relating to the Series A Preferred Shares so that such provision is not inconsistent with the provisions of the Certificate of Incorporation; or

(iii) to waive any of the Corporation’s rights with respect thereto.

 

20


In addition, without the consent or vote of the Holders, and to the fullest extent permitted by applicable law, the Corporation may amend, alter, supplement, or repeal any terms of the Series A Preferred Shares, including by way of amendment to this Certificate of Designations, in order to conform the terms thereof to the description of the terms of the Series A Preferred Shares set forth under “Description of Series A Preferred Shares” in the Offering Memorandum.

(e) Procedures for Voting and Consents. The rules and procedures for calling and conducting any meeting of the Holders (including, without limitation, the fixing of a record date in connection therewith), the solicitation and use of proxies at such a meeting, the obtaining of consents and any other procedural aspect or matter with regard to such a meeting or such consents shall be governed by any rules the Board, in its discretion, may adopt from time to time, which rules and procedures shall conform to the requirements of the Certificate of Incorporation, the Bylaws, applicable law and the rules of any national securities exchange or other trading facility on which the Series A Preferred Shares is listed or traded at the time. Series A Preferred Shares held in nominee or street name account will be voted by the broker or other nominee in accordance with the instruction of the beneficial owner unless the arrangement between the beneficial owner and its nominee provides otherwise.

Section 9. Transfer Agent, Registrar, and Paying Agent.

The Corporation shall maintain in the United States an office or agency where Series A Preferred Shares may be surrendered for payment (including upon redemption), registration of transfer, or exchange. The initial duly appointed Transfer Agent, Registrar and Paying Agent for the Series A Preferred Shares shall be Equiniti Trust Company, LLC. The Corporation may, in its sole discretion, remove the Transfer Agent, Registrar or Paying Agent in accordance with the agreement between the Corporation and the Transfer Agent, Registrar or Paying Agent, as the case may be; provided, however, that if the Corporation removes Equiniti Trust Company, LLC, the Corporation shall appoint a successor transfer agent, registrar or paying agent, as the case may be, who shall accept such appointment prior to the effectiveness of such removal. Upon any such removal or appointment, the Corporation shall send notice thereof to the Holders.

Section 10. Record Holders.

To the fullest extent permitted by applicable law, the Corporation and the Transfer Agent may deem and treat the Holder of any Series A Preferred Shares as the true and lawful owner thereof for all purposes.

Section 11. Notices.

The Corporation shall give all notices or communications to Holders of the Series A Preferred Shares pursuant to this Certificate of Designations in writing by first class mail, postage prepaid, electronically, or pursuant to the procedures of the Securities Depository, to the Holders’ respective addresses shown on the register for the Series A Preferred Shares. Notwithstanding the foregoing, in the case of Series A Preferred Shares held in book-entry form, the Corporation shall be permitted to send notices or communications to Holders pursuant to the procedures of the Securities Depositary, and notices and communications that the Corporation sends in this manner will be deemed to have been properly sent to such Holders in writing. When the terms herein refer

 

21


to a specific agreement or other document or a decision by any body or person that determines the meaning or operation of a provision hereof, the secretary of the Corporation shall maintain a copy of such agreement, document or decision at the principal executive offices of the Corporation and a copy thereof will be provided free of charge to any stockholder who makes a request therefor. Unless expressly provided herein or the context otherwise requires, any definition of or reference to any agreement, instrument or other document herein shall be construed as referring to such agreement, instrument or other document as from time to time amended, restated, supplemented or otherwise modified (subject to any restrictions on such amendments, restatements, supplements or modifications set forth herein).

Section 12. No Preemptive or Conversion Rights.

The Series A Preferred Shares will not be convertible into or exchangeable for any other securities or property, and the Holders will not be entitled to any preemptive or similar rights.

Section 13. Other Rights.

The Series A Preferred Shares shall not have any rights, preferences, privileges or voting powers or relative, participating, optional or other special rights, or qualifications, limitations or restrictions thereof, other than as set forth herein or in the Certificate of Incorporation or as required by applicable law. Series A Preferred Shares will not have the benefit of any sinking fund, and the Corporation is not required to set apart for payment any funds to redeem Series A Preferred Shares.

Section 14. Book-Entry Form.

(a) All Series A Preferred Shares will be represented by one or more global certificates substantially in the form attached hereto as Exhibit A and issued to the Securities Depositary from time to time, and registered in the name of its nominee (initially, Cede & Co.), for credit to an account of a direct or indirect participant in the Securities Depositary (including, if applicable, Euroclear and Clearstream), duly executed by the Corporation and authenticated by the Transfer Agent and Registrar. The Series A Preferred Shares will continue to be represented by one or more global certificates registered in the name of the Securities Depositary or its nominee, and no holder will be entitled to receive a certificate evidencing such shares unless otherwise required by law or the Securities Depositary gives notice of its intention to resign or is no longer eligible to act as such and the Corporation has not selected a substitute Securities Depositary within 90 calendar days thereafter. Payments and communications made by the Corporation to holders will be duly made by making payments to, and communicating with, the Securities Depositary. Accordingly, unless certificates are available to holders, each purchaser of Series A Preferred Shares must rely on (i) the procedures of the Securities Depositary and its participants (including, if applicable, Euroclear and Clearstream) to receive dividends, any redemption price, Liquidation Preference and notices, and to direct the exercise of any voting rights, with respect to such Series A Preferred Shares and (ii) the records of the Securities Depositary and its participants (including, if applicable, Euroclear and Clearstream) to evidence its ownership of such Series A Preferred Shares.

 

22


(b) Notwithstanding anything to the contrary herein, so long as the Securities Depositary (or its nominee) is the sole holder of Series A Preferred Shares, no beneficial holder of Series A Preferred Shares will be deemed to be a holder of Series A Preferred Shares, and the Securities Depositary may be treated by the Corporation, the Transfer Agent, and any agent of the Corporation or the Transfer Agent as the Holder and absolute owner of such Series A Preferred Shares for all purposes whatsoever.

Section 15. Withholding Taxes.

Notwithstanding anything to the contrary, (i) the Corporation and any applicable withholding agent shall be entitled to deduct and withhold from any amounts payable with respect to the Series A Preferred Shares any Taxes required to be so deducted and withheld under applicable law, and (ii) if the Corporation or other applicable withholding agent pays withholding taxes or backup withholding on behalf of the Holder or beneficial owner, the Corporation or other applicable withholding agent may, at its option, set off such payments against payments of cash dividends, shares of Series A Preferred Shares or sale proceeds paid, subsequently paid or credited with respect to such Holder or beneficial owner.

[Signature page follows]

 

23


IN WITNESS WHEREOF, the Corporation has caused this Certificate of Designations to be signed by the undersigned this 30th day of September, 2024.

 

VENTURE GLOBAL LNG, INC.

By:

  /s/ Keith Larson
  Name:  

Keith Larson

  Title:  

General Counsel


Exhibit A

[FORM OF FACE OF

9.00% SERIES A FIXED-RATE RESET CUMULATIVE REDEEMABLE

PERPETUAL PREFERRED STOCK CERTIFICATE]

THE SHARES EVIDENCED HEREBY HAVE NOT BEEN REGISTERED UNDER THE U.S. SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”) AND MAY NOT BE OFFERED, SOLD, PLEDGED OR OTHERWISE TRANSFERRED IN THE ABSENCE OF SUCH REGISTRATION OR IN A TRANSACTION EXEMPT FROM, OR NOT SUBJECT TO, SUCH REGISTRATION. THE HOLDER OF THE SHARES EVIDENCED HEREBY, BY ITS ACCEPTANCE HEREOF, AGREES ON ITS OWN BEHALF AND ON BEHALF OF ANY INVESTOR ACCOUNT FOR WHICH IT HAS PURCHASED SUCH SHARES, NOT TO OFFER, SELL OR OTHERWISE TRANSFER SUCH SHARES PRIOR TO THE DATE THAT IS IN THE CASE OF A RULE 144A CERTIFICATE: ONE YEAR AFTER THE LATER OF THE DATE OF ORIGINAL ISSUANCE OF SUCH SHARES AND THE LAST DATE ON WHICH THE COMPANY OR ANY AFFILIATE OF THE COMPANY WAS THE OWNER OF SUCH SHARES OR ANY BENEFICIAL INTEREST THEREIN IN THE CASE OF A REGULATION S CERTIFICATE: 40 (FORTY) DAYS AFTER THE LATER OF (X) THE CLOSING DATE OF THE OFFERING PURSUANT TO WHICH SUCH SHARES WERE ORIGINALLY ISSUED AND (Y) THE DATE ON WHICH SUCH SHARES OR ANY PREDECESSOR OF SUCH SHARES WERE FIRST OFFERED TO PERSONS OTHER THAN DISTRIBUTORS (AS DEFINED IN RULE 902 OF REGULATION S) (SUCH DATE, THE “RELEASE DATE”), EXCEPT (A) (1) IN A TRANSACTION MEETING THE REQUIREMENTS OF RULE 144A UNDER THE SECURITIES ACT (FOR SO LONG AS THE SHARES ARE ELIGIBLE FOR RESALE UNDER RULE 144A UNDER THE SECURITIES ACT) TO A PERSON WHO THE SELLER REASONABLY BELIEVES IS A QUALIFIED INSTITUTIONAL BUYER WITHIN THE MEANING OF RULE 144A UNDER THE SECURITIES ACT PURCHASING FOR ITS OWN ACCOUNT OR FOR THE ACCOUNT OF A QUALIFIED INSTITUTIONAL BUYER AND TO WHOM NOTICE IS GIVEN THAT THE TRANSFER IS BEING MADE IN RELIANCE ON RULE 144A UNDER THE SECURITIES ACT, (2) IN AN OFFSHORE TRANSACTION COMPLYING WITH RULE 903 OR RULE 904 OF REGULATION S UNDER THE SECURITIES ACT, (3) PURSUANT TO AN EXEMPTION FROM REGISTRATION UNDER THE SECURITIES ACT PROVIDED BY RULE 144 THEREUNDER (IF AVAILABLE) OR ANY OTHER AVAILABLE EXEMPTION FROM THE REGISTRATION REQUIREMENTS OF THE SECURITIES ACT, (4) PURSUANT TO AN EFFECTIVE REGISTRATION STATEMENT UNDER THE SECURITIES ACT OR (5) TO THE COMPANY, PROVIDED THAT ANY OFFER, SALE, PLEDGE OR OTHER TRANSFER PURSUANT TO CLAUSE (1) OR (2) SHALL BE SUBJECT TO THE RIGHT OF THE COMPANY AND/OR THE TRANSFER AGENT TO REQUIRE THE DELIVERY OF AN OPINION OF COUNSEL, CERTIFICATION AND/OR OTHER INFORMATION SATISFACTORY TO EACH OF THEM; AND (B) IN ACCORDANCE WITH ALL APPLICABLE SECURITIES LAWS OF THE STATES OF THE U.S. AND OTHER JURISDICTIONS AND SUBJECT TO ANY REQUIREMENT OF LAW THAT THE DISPOSITION OF THE SELLER’S PROPERTY OR THE PROPERTY OF AN INVESTOR ACCOUNT OR ACCOUNTS BE AT ALL TIMES WITH THE SELLER OR ACCOUNT’S CONTROL.

 

Exh A-1


IN ADDITION, THE HOLDER OF THIS SECURITY UNDERSTANDS THAT THE COMPANY MAY RECEIVE A LIST OF PARTICIPANTS HOLDING POSITIONS IN THIS SECURITY FROM ONE OR MORE BOOK-ENTRY DEPOSITARIES. EACH PURCHASER OF THIS SECURITY OR ANY BENEFICIAL INTERESTS HEREIN WILL BE DEEMED TO REPRESENT THAT IT AGREES TO COMPLY WITH THE TRANSFER RESTRICTIONS SET FORTH HEREIN AND IN THE CERTIFICATE OF DESIGNATIONS, AND WILL NOT TRANSFER THIS SECURITY OR ANY BENEFICIAL INTERESTS HEREIN EXCEPT TO AN ELIGIBLE PURCHASER WHO CAN MAKE THE SAME ACKNOWLEDGMENTS, REPRESENTATIONS, WARRANTIES AND AGREEMENTS ON BEHALF OF ITSELF AND EACH ACCOUNT FOR WHICH IT IS PURCHASING.

UNLESS THIS CERTIFICATE IS PRESENTED BY AN AUTHORIZED REPRESENTATIVE OF THE DEPOSITORY TRUST COMPANY, A NEW YORK CORPORATION (“DTC”), TO THE CORPORATION OR THE TRANSFER AGENT NAMED ON THE FACE OF THIS CERTIFICATE, AND ANY CERTIFICATE ISSUED IS REGISTERED IN THE NAME OF CEDE & CO. OR IN SUCH OTHER NAME AS IS REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC (AND ANY PAYMENT IS MADE TO CEDE & CO., OR TO SUCH OTHER ENTITY AS IS REQUESTED BY AN AUTHORIZED REPRESENTATIVE OF DTC), ANY TRANSFER, PLEDGE OR OTHER USE HEREOF FOR VALUE OR OTHERWISE BY OR TO ANY PERSON IS WRONGFUL IN AS MUCH AS THE REGISTERED OWNER HEREOF, CEDE & CO. HAS AN INTEREST HEREIN. TRANSFERS OF THIS GLOBAL SECURITY SHALL BE LIMITED TO TRANSFERS IN WHOLE, BUT NOT IN PART, TO DTC OR NOMINEES OF DTC OR TO A SUCCESSOR THEREOF OR SUCH SUCCESSOR’S NOMINEE.

 

Exh A-2


Certificate Number [•]    Initial Number of Shares of 9.00% Series A Fixed-Rate Reset
   Cumulative Redeemable Perpetual Preferred Stock: [•]
   [CUSIP: [•]]
   [ISIN: [•]]

VENTURE GLOBAL LNG, INC.

9.00% Series A Fixed-Rate Reset Cumulative Redeemable Perpetual Preferred Stock

(Liquidation Preference as specified below)

Venture Global LNG, Inc., a Delaware corporation (the “Corporation”), hereby certifies that Cede & Co. (the “Holder”), is the registered owner of [•], or as set forth in Schedule I attached hereto, fully paid and non-assessable shares of the Corporation’s designated 9.00% Series A Fixed- Rate Reset Cumulative Redeemable Perpetual Preferred Stock, with a Liquidation Preference of $1,000.00 per share (the “Series A Preferred Shares”). The Series A Preferred Shares are transferable on the books and records of the Registrar, in person or by a duly authorized attorney, upon surrender of this certificate duly endorsed and in proper form for transfer. The designations, rights, privileges, restrictions, preferences and other terms and provisions of the Series A Preferred Shares represented hereby are and shall in all respects be subject to the provisions of the Certificate of Designations of 9.00% Series A Fixed-Rate Reset Cumulative Redeemable Perpetual Preferred Stock, of Venture Global LNG, Inc. dated September 30, 2024, as the same may be amended from time to time (the “Certificate of Designations”). Capitalized terms used herein but not defined shall have the meanings given them in the Certificate of Designations. The Corporation will provide a copy of the Certificate of Designations to the Holder without charge upon written request to the Corporation at its principal place of business.

Reference is hereby made to the provisions of the Series A Preferred Shares set forth on the reverse hereof and in the Certificate of Designations, which provisions shall for all purposes have the same effect as if set forth at this place. If the terms of this certificate conflict with the terms of the Certificate of Designations, then the terms of the Certificate of Designations will control to the extent of such conflict.

Upon receipt of this executed certificate, the Holder is bound by the Certificate of Designations and is entitled to the benefits thereunder.

Unless the Transfer Agent and Registrar have properly countersigned this certificate, these Series A Preferred Shares shall not be entitled to any benefit under the Certificate of Designations or be valid or obligatory for any purpose.

* * *

 

Exh A-3


IN WITNESS WHEREOF, this certificate has been executed on behalf of the Corporation by two authorized officers of the Corporation this [•] day of [•], 20[•].

 

VENTURE GLOBAL LNG, INC.

By:

   
  Name:  
  Title:  

By:

   
  Name:  
  Title:  
   

 

Exh A-4


COUNTERSIGNATURE

These are the Series A Preferred Shares referred to in the within-mentioned Certificate of Designations.

Dated: [•], [•]

 

Equiniti Trust Company, LLC, as Registrar and Transfer Agent

By:

   
  Name:  
  Title:  

 

Exh A-5


[FORM OF REVERSE OF

CERTIFICATE FOR SERIES A PREFERRED STOCK]

Cumulative cash distributions on each Series A Preferred Share shall be payable at the rate provided in the Certificate of Designations.

The Corporation shall furnish without charge to each Holder who so requests a statement of the rights, preferences, privileges and restrictions granted to or imposed upon each class or series of stock of the Corporation authorized to be issued, including the Series A Preferred Shares, and upon the holders thereof. Such statement may be obtained from the Corporation at the Corporation’s principal executive office, which, on September 30, 2024, was located at 1001 19th Street North, Suite 1500, Arlington, VA, 22209.

 

Exh A-6


ASSIGNMENT

FOR VALUE RECEIVED, the undersigned assigns and transfers the Series A Preferred Shares evidenced hereby to:

(Insert assignee’s social security or taxpayer identification number, if any)

 

 
 
 

(Insert address and zip code of assignee)

and irrevocably appoints: [•]

as agent to transfer the Series A Preferred Shares evidenced hereby on the books of the Transfer Agent and Registrar. The agent may substitute another to act for him or her.

Date:

 

Signature:      
 

(Sign exactly as your name appears on the

other side of this Certificate)

 
Signature Guarantee:      
  (Signature must be guaranteed by an “eligible guarantor institution” that is a bank, stockbroker, savings and loan association or credit union meeting the requirements of the Transfer Agent, which requirements include membership or participation in the Securities Transfer Agents Medallion Program (“STAMP”) or such other “signature guarantee program” as may be determined by the Transfer Agent in addition to, or in substitution for, STAMP, all in accordance with the Securities Exchange Act of 1934, as amended.)  

 

Exh A-7


Schedule I1

to Certificate of Designations

VENTURE GLOBAL LNG, INC.

Global Preferred Share

9.00% Series A Fixed-Rate Reset Cumulative Redeemable Perpetual Preferred Stock

Certificate Number:

The number of Series A Preferred Shares initially represented by this Global Preferred Share shall be [•]. Thereafter the Transfer Agent and Registrar shall note changes in the number of Series A Preferred Shares evidenced by this Global Preferred Share in the table set forth below

 

Amount of Decrease in

Number of Shares

Represented by this Global

Preferred Share

 

Amount of Increase in

Number of Shares

Represented by this Global

Preferred Share

 

Number of Shares

Represented by this Global

Preferred Share following

Decrease or Increase

  

Signature of Authorized

Officer of Transfer Agent and

Registrar

                          
 

 

 

 

  

 

 

1 

Attach Schedule I only to Global Preferred Shares.

 

Exh A-8

Exhibit 10.101

 

 

VENTURE GLOBAL, INC.

2023 STOCK OPTION PLAN

(As amended and restated November 14, 2024)

 

 


TABLE OF CONTENTS

 

     Page  

1.   PURPOSE

     1  

2.   DEFINITIONS

     1  

3.   ADMINISTRATION OF THE PLAN

     7  

3.1   Committee

     7  

3.1.1   Powers and Authorities

     7  

3.1.2   Composition of Committee

     7  

3.1.3   Other Committees

     7  

3.1.4   Delegation by Committee

     8  

3.2   Board

     8  

3.3   Terms of Awards

     8  

3.3.1   Committee Authority

     8  

3.3.2   Forfeiture; Recoupment

     9  

3.4   No Repricing Without Stockholder Approval

     9  

3.5   No Liability

     10  

3.6   Registration; Share Certificates

     10  

4.   STOCK SUBJECT TO THE PLAN

     10  

4.1   Number of Shares of Stock Available for Awards

     10  

4.2   Adjustments in Authorized Shares of Stock

     10  

4.3   Share Usage

     11  

5.   TERM; AMENDMENT AND TERMINATION

     11  

5.1   Term

     11  

5.2   Amendment and Termination

     11  

6.   AWARD ELIGIBILITY AND LIMITATIONS

     11  

6.1   Eligible Grantees

     11  

6.2   Stand-Alone, Additional and Substitute Awards

     11  

7.   AWARD AGREEMENT

     12  

8.   TERMS AND CONDITIONS OF OPTIONS

     12  

8.1   Option Price

     12  

8.2   Vesting and Exercisability

     12  

8.3   Term

     12  

8.4   Termination of Service

     13  

8.5   Limitations on Exercise of Option

     13  

8.6   Method of Exercise

     13  

8.7   Rights of Holders of Options

     13  

8.8   Delivery of Stock

     13  

8.9   Transferability of Options

     14  

8.10  Family Transfers

     14  

8.11  Limitations on Incentive Stock Options

     14  

8.12  Notice of Disqualifying Disposition

     14  

 

i


9.   FORM OF PAYMENT FOR OPTIONS

     15  

9.1   General Rule

     15  

9.2   Surrender of Shares of Stock

     15  

9.3   Cashless Exercise

     15  

9.4   Other Forms of Payment

     15  

10.  Restrictions on Transfer of Shares of Stock

     15  

10.1  Right of First Refusal

     15  

10.2  Repurchase and Other Rights

     16  

10.3  Market Stand-Off

     16  

10.4  Legend

     16  

11.  PARACHUTE LIMITATIONS

     16  

12.  REQUIREMENTS OF LAW

     17  

12.1  General

     17  

12.2  Rule 16b-3

     17  

13.  EFFECT OF CHANGES IN CAPITALIZATION

     18  

13.1  Changes in Stock

     18  

13.2  Reorganization in Which the Company Is the Surviving Entity Which Does not Constitute a Change in Control

     18  

13.3  Change in Control in which Awards are not Assumed

     19  

13.4  Change in Control in which Awards are Assumed

     19  

13.5  Adjustments

     19  

13.6  No Limitations on Company

     20  

14.  GENERAL PROVISIONS

     20  

14.1  Shareholders’ Agreement

     20  

14.2  Disclaimer of Rights

     20  

14.3  Nonexclusivity of the Plan

     20  

14.4  Withholding Taxes

     21  

14.5  Captions

     21  

14.6  Construction

     21  

14.7  Other Provisions

     21  

14.8  Number and Gender

     21  

14.9  Severability

     22  

14.10  Governing Law

     22  

14.11  Section 409A of the Code

     22  

 

ii


VENTURE GLOBAL, INC.

2023 STOCK OPTION PLAN

1. PURPOSE

The Plan is being adopted in connection with the reorganization transactions involving Venture Global LNG, Inc., a Delaware corporation (“VGLNG”), and its affiliates, as a result of which all shares of Series A Common Stock of VGLNG outstanding prior to the commencement of such transactions were exchanged, on a one-for-one basis, for shares of Class A Common Stock of the Company, and options outstanding under the Predecessor Plan to purchase shares of Series A Common Stock of VGLNG were automatically converted, on a one-for-one basis, in accordance with and pursuant to the terms of the Predecessor Plan, into Options to purchase shares of Class A Common Stock subject to the terms and conditions of this Plan.

The Plan is intended to (a) provide eligible individuals with an incentive to contribute to the success of the Company and to operate and manage the Company’s business in a manner that will provide for the Company’s long-term growth and profitability to benefit its stockholders and other important stakeholders, including its employees and customers, and (b) provide a means of obtaining, rewarding and retaining key personnel. To this end, the Plan provides for the grant of awards of stock options, which may be Non-qualified Stock Options or Incentive Stock Options, as provided herein.

2. DEFINITIONS

For purposes of interpreting the Plan documents (including the Plan and Award Agreements), the following definitions shall apply:

2.1 Affiliate” means any company or other entity that controls, is controlled by or is under common control with the Company within the meaning of Rule 405 of Regulation C under the Securities Act, including any Subsidiary. An entity may not be considered an Affiliate unless the Company holds a Controlling Interest in such entity, provided that (a) except as specified in clause (b) below, an interest of “at least 50 percent” shall be used instead of an interest of “at least 80 percent” in each case where “at least 80 percent” appears in Treasury Regulation Section 1.414(c)-2(b)(2)(i) and (b) where the grant of Options is based upon a legitimate business criterion, an interest of “at least 20 percent” shall be used instead of an interest of “at least 80 percent” in each case where “at least 80 percent” appears in Treasury Regulation Section 1.414(c)-2(b)(2)(i).

2.2 Applicable Laws” means the legal requirements relating to the Plan and the Awards under (a) applicable provisions of the corporate, securities, tax and other laws, rules, regulations and government orders of any jurisdiction applicable to Awards granted to residents therein and (b) the rules of any Stock Exchange on which the Stock is listed.

2.3 Award” means a grant under the Plan of an Option.

2.4 Award Agreement” means the agreement between the Company and a Grantee that evidences and sets out the terms and conditions of an Award.

 

1


2.5 Beneficial Owner” shall have the meaning set forth in Rule 13d-3 under the Exchange Act.

2.6 Benefit Arrangement” shall mean any formal or informal plan or other arrangement for the direct or indirect provision of compensation to a Grantee (including groups or classes of Grantees or beneficiaries of which the Grantee is a member), whether or not such compensation is deferred, is in cash, or is in the form of a benefit to or for the Grantee.

2.7 Board” means the Board of Directors of the Company.

2.8 Cause” means, with respect to any Grantee, as determined by the Committee and unless otherwise provided in an applicable agreement between such Grantee and the Company or an Affiliate, (a) gross negligence or willful misconduct in connection with the performance of duties; (b) conviction of, or pleading of nolo contendere to, a felony or other criminal offense that is injurious to the Company; or (c) material breach of any term of any employment, consulting or other services, confidentiality, intellectual property or non-competition agreements, if any, between such Grantee and the Company or an Affiliate. Any determination by the Committee whether an event constituting Cause shall have occurred shall be final, binding and conclusive.

2.9 Capital Stock” means, with respect to any Person, any and all shares, interests, participations or other equivalents (however designated, whether voting or non-voting) in equity of such Person, whether outstanding on September 25, 2023 or issued thereafter, including, without limitation, all Class A Common Stock, par value $0.01 per share, of the Company.

2.10 Change in Control” means the occurrence of any of the following:

(a) during any time when the Company has a class of equity security registered under Section 12 of the Exchange Act, a Person or Group becomes the Beneficial Owner of more than fifty percent (50%) of the total voting power of the Voting Stock of the Company, on a Fully Diluted Basis;

(b) during any time when the Company has a class of equity security registered under Section 12 of the Exchange Act, individuals who on the effective date of registration under Section 12 of the Exchange Act constitute the Board (together with any new directors whose election by such Board or whose nomination by such Board for election by the stockholders of the Company was approved by a vote of at least a majority of the members of such Board then in office who either were members of such Board on such effective date or whose election or nomination for election was previously so approved) cease for any reason to constitute a majority of the members of such Board then in office;

(c) the Company consolidates with, or merges with or into, any Person, or any Person consolidates with, or merges with or into, the Company, other than any such transaction in which the Prior Stockholders own directly or indirectly at least a majority of the voting power of the Voting Stock of the surviving Person in such merger or consolidation transaction immediately after such transaction, unless this event occurs prior to the time when the Company has a class of equity security registered under Section 12 of the Exchange Act and the Prior Stockholders continue to exercise direct or indirect control of the management and operation of the Company;

 

2


(d) there is consummated any direct or indirect sale, lease, transfer, conveyance or other disposition (other than by way of merger or consolidation), in one transaction or a series of related transactions, of all or substantially all of the assets of the Company and its Subsidiaries, taken as a whole, to any Person or Group, other than a sale, lease, transfer, conveyance or other disposition to a special purpose entity that is a wholly-owned Subsidiary of the Company for project financing purposes; or

(e) the stockholders of the Company adopt a plan or proposal for the liquidation, winding up or dissolution of the Company.

2.11 Code” means the Internal Revenue Code of 1986, as amended, as now in effect or as hereafter amended, and any successor thereto. References in the Plan to any Code Section shall be deemed to include, as applicable, regulations promulgated under such Code Section.

2.12 Committee” means a committee of, and designated from time to time by resolution of, the Board, which shall be constituted as provided in Section 3.1.2 (or, if no Committee has been so designated, the Board).

2.13 Company” means Venture Global, Inc., a Delaware corporation.

2.14 Controlling Interest” shall have the meaning set forth in Treasury Regulation Section 1.414(c)-2(b)(2)(i).

2.15 Covered Employee” means a Grantee who is a “covered employee” within the meaning of Code Section 162(m)(3).

2.16 Disability” means the inability of a Grantee to perform each of the essential duties of such Grantee’s position by reason of a medically determinable physical or mental impairment which is potentially permanent in character or which can be expected to last for a continuous period of not less than 12 months; provided that, with respect to rules regarding expiration of an Incentive Stock Option following termination of a Grantee’s Service, Disability shall mean the inability of such Grantee to engage in any substantial gainful activity by reason of a medically determinable physical or mental impairment which can be expected to result in death or which has lasted or can be expected to last for a continuous period of not less than 12 months.

2.17 Disqualified Individual” shall have the meaning set forth in Code Section 280G(c).

2.18 Effective Date” means December 16, 2014, which was the effective date of the Predecessor Plan.

2.19 Employee” means, as of any date of determination, an employee (including an officer) of the Company or an Affiliate.

2.20 Exchange Act” means the Securities Exchange Act of 1934, as amended, as now in effect or as hereafter amended.

 

3


2.21 Fair Market Value” means the fair market value of a share of Stock for purposes of the Plan, which shall be determined as of any determination date as follows:

(a) If on such date the shares of Stock are listed on a Stock Exchange, or are publicly traded on another Securities Market, the Fair Market Value of a share of Stock shall be the closing price of the Stock on such date as reported on such Stock Exchange or such Securities Market (provided that, if there is more than one such Stock Exchange or Securities Market, the Committee shall designate the appropriate Stock Exchange or Securities Market for purposes of the Fair Market Value determination). If there is no such reported closing price on the determination date, the Fair Market Value of a share of Stock shall be the closing price of the Stock on the next preceding day on which any sale of Stock shall have been reported on such Stock Exchange or such Securities Market.

(b) If on such date the shares of Stock are not listed on a Stock Exchange or publicly traded on a Securities Market, the Fair Market Value of a share of Stock shall be the value of the Stock as determined by the Committee by the reasonable application of a reasonable valuation method, in a manner consistent with Code Section 409A.

Notwithstanding this Section 2.21 or Section 14.4, for purposes of determining taxable income and the amount of the related tax withholding obligation pursuant to Section 14.4, for any shares of Stock subject to an Option that are sold by or on behalf of a Grantee on the same date on which such shares may first be sold pursuant to the terms of the related Award Agreement, the Fair Market Value of such shares shall be the sale price of such shares on such date (or if sales of such shares are effectuated at more than one sale price, the weighted average sale price of such shares on such date).

2.22 Family Member” means, with respect to any Grantee as of any date of determination, (a) a Person who is a spouse, former spouse, child, stepchild, grandchild, parent, stepparent, grandparent, niece, nephew, mother-in-law, father-in-law, son-in-law, daughter-in-law, brother, sister, brother-in-law, or sister-in-law, including adoptive relationships, of such Grantee, (b) any Person sharing such Grantee’s household (other than a tenant or employee), (c) a trust in which any one or more of the Persons specified in clauses (a) and (b) above (and such Grantee) own more than fifty percent (50%) of the beneficial interest, (d) a foundation in which any one or more of the Persons specified in clauses (a) and (b) above (and such Grantee) control the management of assets, and (e) any other entity in which one or more of the Persons specified in clauses (a) and (b) above (and such Grantee) own more than fifty percent (50%) of the voting interests.

2.23 Fully Diluted Basis” means, as of any date of determination, the sum of (x) the number of shares of Voting Stock outstanding as of such date of determination plus (y) the number of shares of Voting Stock issuable upon the exercise, conversion or exchange of all then-outstanding warrants, options, convertible Capital Stock or indebtedness, exchangeable Capital Stock or indebtedness, or other rights exercisable for or convertible or exchangeable into, directly or indirectly, shares of Voting Stock, whether at the time of issue or upon the passage of time or upon the occurrence of some future event, and whether or not in the money as of such date of determination

2.24 Grant Date” means, as determined by the Committee, the latest to occur of (a) the date as of which the Committee approves the Award, (b) the date on which the recipient of an Award first becomes eligible to receive an Award under Article 6 hereof (e.g., in the case of a new hire, the first date on which such new hire performs any Service), or (c) such subsequent date specified by the Committee in the corporate action approving the Award.

2.25 Grantee” means a Person who receives or holds an Award under the Plan.

 

4


2.26 Group” shall have the meaning set forth in Sections 13(d) and 14(d)(2) of the Exchange Act.

2.27 “Incentive Stock Option” means an “incentive stock option” within the meaning of Code Section 422, or the corresponding provision of any subsequently enacted tax statute, as amended from time to time.

2.28 Initial Public Offering” or “IPO” means the initial underwritten registered public offering by the Company of the Stock.

2.29 “Non-qualified Stock Option” means an Option that is not an Incentive Stock Option.

2.30 Officer” shall have the meaning set forth in Rule 16a-1(f) under the Exchange Act.

2.31 Option” means an option to purchase one or more shares of Stock pursuant to the Plan.

2.32 Option Price” means the exercise price for each share of Stock subject to an Option.

2.33 Other Agreement” means any agreement, contract, or understanding heretofore or hereafter entered into by a Grantee with the Company or an Affiliate, except an agreement, contract, or understanding that expressly addresses Code Section 280G or Code Section 4999.

2.34 Outside Director” shall have the meaning set forth in Code Section 162(m)(4)(C)(i).

2.35 Parachute Payment” means a “parachute payment” within the meaning of Code Section 280G(b)(2) as then in effect.

2.36 Person” means an individual, a corporation, a partnership, a limited liability company, an association, a trust or any other entity or organization, including a government or political subdivision or an agency or instrumentality thereof; provided that for purposes of Section 2.10(a) and Section 2.10(d), Person shall have the meaning set forth in Sections 13(d) and 14(d)(2) of the Exchange Act.

2.37 Plan” means the Company’s 2023 Stock Option Plan, as amended from time to time (including any predecessor or successor plan thereto, including, for the avoidance of doubt, the Predecessor Plan).

2.38 Predecessor Plan” means the Venture Global LNG, Inc. 2014 Stock Option Plan (as amended from time to time).

2.39 Prior Stockholders” mean the holders of securities that represented one hundred percent (100%) of the Voting Stock of the Company immediately prior to a merger or consolidation involving the Company (or other securities into which such securities are converted as part of such merger or consolidation transaction).

2.40 Securities Act” means the Securities Act of 1933, as amended, as now in effect or as hereafter amended.

2.41 Securities Market” means an established securities market.

 

5


2.42 Separation from Service” shall have the meaning set forth in Code Section 409A and the regulations promulgated thereunder.

2.43 Service” means service qualifying a Grantee as a Service Provider to the Company or an Affiliate. Unless otherwise provided in the applicable Award Agreement, a Grantee’s change in position or duties shall not result in interrupted or terminated Service, so long as such Grantee continues to be a Service Provider to the Company or an Affiliate. Subject to the preceding sentence, any determination by the Committee whether a termination of Service shall have occurred for purposes of the Plan shall be final, binding and conclusive. If a Service Provider’s employment or other service relationship is with an Affiliate and the applicable entity ceases to be an Affiliate, a termination of Service shall be deemed to have occurred when such entity ceases to be an Affiliate unless the Service Provider transfers his or her employment or other service relationship to the Company or any other Affiliate.

2.44 Service Provider” means an Employee, officer, or director of the Company or an Affiliate, or a consultant or adviser (who is a natural Person) to the Company or an Affiliate currently providing services to the Company or an Affiliate.

2.45 Service Recipient Stock” shall have the meaning set forth in Code Section 409A and the regulations promulgated thereunder.

2.46 Short-Term Deferral Period” shall have the meaning set forth in Code Section 409A and the regulations promulgated thereunder.

2.47 Stock” means the Class A Common Stock, par value $0.01 per share, of the Company, or any security which shares of Stock may be changed into or for which shares of Stock may be exchanged as provided in Section 13.1.

2.48 “Shareholders’ Agreement” means the Company’s shareholders agreement relating to its Capital Stock, as the agreement may be amended from time to time.

2.49 Stock Exchange” means an established national or regional stock exchange.

2.50 Subsidiary” means any corporation (other than the Company) or non-corporate entity with respect to which the Company owns, directly or indirectly, fifty percent (50%) or more of the total combined voting power of all classes of stock, membership interests or other ownership interests of any class or kind ordinarily having the power to vote for the directors, managers or other voting members of the governing body of such corporation or non-corporate entity. In addition, any other entity may be designated by the Committee as a Subsidiary, provided that (a) such entity could be considered as a subsidiary according to generally accepted accounting principles in the United States of America, and (b) an Award would be considered to be granted in respect of Service Recipient Stock under Code Section 409A.

2.51 Substitute Award” means an Award granted upon assumption of, or in substitution for, outstanding awards previously granted under a compensatory plan by a business entity acquired or to be acquired by the Company or an Affiliate or with which the Company or an Affiliate has combined or will combine.

 

6


2.52 “Ten Percent Stockholder” means a natural Person who owns more than ten percent (10%) of the total combined voting power of all classes of outstanding voting securities of the Company, the Company’s parent (if any) or any of the Company’s Subsidiaries. In determining stock ownership, the attribution rules of Code Section 424(d) shall be applied.

2.53 Voting Stock” means, with respect to any Person, Capital Stock of any class or kind ordinarily having the power to vote for the election of directors, managers or other voting members of the governing body of such Person.

3. ADMINISTRATION OF THE PLAN

3.1 Committee.

3.1.1 Powers and Authorities.

The Committee shall administer the Plan and shall have such powers and authorities related to the administration of the Plan as are consistent with the Company’s certificate of incorporation and bylaws and Applicable Laws. Without limiting the generality of the foregoing, the Committee shall have full power and authority to take all actions and to make all determinations required or provided for under the Plan, any Award or any Award Agreement, and shall have full power and authority to take all such other actions and make all such other determinations not inconsistent with the specific terms and provisions of the Plan which the Committee deems to be necessary or appropriate to the administration of the Plan, any Award or any Award Agreement. All such actions and determinations shall be made by (a) the affirmative vote of a majority of the members of the Committee present at a meeting at which a quorum is present, or (b) the unanimous consent of the members of the Committee executed in writing in accordance with the Company’s certificate of incorporation and bylaws and Applicable Laws. Unless otherwise expressly determined by the Board, the Committee shall have the authority to interpret and construe all provisions of the Plan, any Award and any Award Agreement, and any such interpretation or construction, and any other determination contemplated to be made under the Plan or any Award Agreement, by the Committee shall be final, binding and conclusive whether or not expressly provided for in any provision of the Plan, such Award or such Award Agreement.

In the event that the Plan, any Award or any Award Agreement provides for any action to be taken by the Board or any determination to be made by the Board, such action may be taken or such determination may be made by the Committee constituted in accordance with this Section 3.1 if the Board has delegated the power and authority to do so to such Committee.

3.1.2 Composition of Committee.

The Committee shall be a committee composed of not fewer than two directors of the Company designated by the Board to administer the Plan. Without limiting the generality of the foregoing, the Committee may be the Compensation Committee of the Board or a subcommittee thereof if the Compensation Committee of the Board or such subcommittee satisfies the foregoing requirements.

3.1.3 Other Committees.

The Board also may appoint one or more committees of the Board, each composed of one or more directors of the Company who need not be Outside Directors, which may administer the Plan with respect to Grantees who are not Officers or directors of the Company, may grant Awards under the Plan to such Grantees, and may determine all terms of such Awards, subject, if applicable, to the requirements of Rule 16b-3 under the Exchange Act, Code Section 162(m) and the rules of any Stock Exchange on which the Stock is listed.

 

7


3.1.4 Delegation by Committee.

To the extent permitted by Applicable Laws, the Committee may by resolution delegate some or all of its authority with respect to the Plan and Awards to the Chief Executive Officer of the Company and/or any other officer of the Company designated by the Committee, provided that, if the shares of Stock are listed on a Stock Exchange or are publicly traded on a Securities Market, or if otherwise required by Applicable Law, the Committee may not delegate its authority hereunder (a) to make Awards to directors of the Company, (b) to make Awards to Employees who are (i) Officers, (ii) Covered Employees or (iii) officers of the Company who are delegated authority by the Committee pursuant to this Section 3.1.4, or (c) to interpret the Plan or any Award. Any delegation hereunder will be subject to the restrictions and limits that the Committee specifies at the time of such delegation or thereafter. Nothing in the Plan will be construed as obligating the Committee to delegate authority to any officer of the Company, and the Committee may at any time rescind the authority delegated to an officer of the Company appointed hereunder and delegate authority to one or more other officers of the Company. At all times, an officer of the Company delegated authority pursuant to this Section 3.1.4 will serve in such capacity at the pleasure of the Committee. Any action undertaken by any such officer of the Company in accordance with the Committee’s delegation of authority will have the same force and effect as if undertaken directly by the Committee, and any reference in the Plan to the “Committee” will, to the extent consistent with the terms and limitations of such delegation, be deemed to include a reference to each such officer.

3.2 Board.

The Board from time to time may exercise any or all of the powers and authorities related to the administration and implementation of the Plan, as set forth in Section 3.1 and other applicable provisions of the Plan, as the Board shall determine, consistent with the Company’s certificate of incorporation and bylaws and Applicable Laws.

3.3 Terms of Awards.

3.3.1 Committee Authority.

Subject to the other terms and conditions of the Plan, the Committee shall have full and final authority to:

(a) designate Grantees;

(b) determine the type of Option to be awarded to a Grantee;

(c) determine the number of shares of Stock to be subject to an Award;

(d) establish the terms and conditions of each Award (including the Option Price of any Option), the nature and duration of any restriction or condition (or provision for lapse thereof) relating to the vesting, exercise, transfer, or forfeiture of an Award or the shares of Stock subject thereto, the treatment of an Award in the event of a Change in Control (subject to applicable agreements), and any terms or conditions that may be necessary to qualify Options as Incentive Stock Options;

 

8


(e) prescribe the form of each Award Agreement evidencing an Award; and

(f) subject to the limitation on repricing in Section 3.4, amend, modify or supplement the terms of any outstanding Award, which authority shall include the authority, in order to effectuate the purposes of the Plan but without amending the Plan, to make Awards or to modify outstanding Awards made to eligible natural Persons who are foreign nationals or are natural Persons who are employed outside the United States to reflect differences in local law, tax policy, or custom, provided that, notwithstanding the foregoing, no amendment, modification or supplement of the terms of any outstanding Award shall, without the consent of the Grantee thereof, impair such Grantee’s rights under such Award.

The Committee shall have the right, in its discretion, to make Awards in substitution or exchange for any award granted under another compensatory plan of the Company, an Affiliate, or any business entity acquired or to be acquired by the Company or an Affiliate or with which the Company or an Affiliate has combined or will combine.

3.3.2 Forfeiture; Recoupment.

The Committee may reserve the right in an Award Agreement to cause a forfeiture of the gain realized by a Grantee with respect to an Award thereunder on account of actions taken by, or failed to be taken by, such Grantee in violation or breach of or in conflict with any (a) employment agreement, (b) non-competition agreement, (c) agreement prohibiting solicitation of Employees or clients of the Company or an Affiliate, (d) confidentiality obligation with respect to the Company or an Affiliate, (e) Company policy or procedure, (f) other agreement, or (g) any other obligation of such Grantee to the Company or an Affiliate, as and to the extent specified in such Award Agreement. The Committee may annul an outstanding Award if the Grantee thereof is an Employee of the Company or an Affiliate and is terminated for Cause.

Any Award granted pursuant to the Plan shall be subject to mandatory repayment by the Grantee to the Company to the extent the Grantee is, or in the future becomes, subject to (x) any Company “clawback” or recoupment policy that is adopted to comply with the requirements of any Applicable Law, rule or regulation, or (y) any law, rule or regulation which imposes mandatory recoupment, under circumstances set forth in such law, rule or regulation.

3.4 No Repricing Without Stockholder Approval.

Except in connection with a corporate transaction involving the Company (including, without limitation, any stock dividend, distribution (whether in the form of cash, shares of Stock, other securities or other property), stock split, extraordinary cash dividend, recapitalization, change in control, reorganization, merger, consolidation, split-up, spin-off, combination, repurchase or exchange of shares of Stock or other securities or similar transaction), during any time when the Company has a class of equity security registered under Section 12 of the Exchange Act, the Company may not, without obtaining stockholder approval: (a) amend the terms of outstanding Options to reduce the exercise price of such outstanding Options; (b) cancel outstanding Options in exchange for or substitution of Options with an exercise price that is less than the exercise price of the original Options; or (c) cancel outstanding Options with an exercise price above the current stock price in exchange for cash or other securities. Notwithstanding the foregoing, during any time when the Company has a class of equity security registered under Section 12 of the Exchange Act, the Committee may not grant Options in replacement of Options previously granted under this Plan or any other compensation plan of the Company or cancel an

 

9


outstanding Option in exchange for cash (other than cash with a value equal to the excess of the Fair Market Value of the Stock subject to such Option at the time of cancellation over the exercise or grant price for such Stock), or may the Committee amend outstanding Options (including amendments to adjust an Option price) unless such replacement or adjustment (i) is subject to and approved by the Company’s stockholders or (ii) would not be deemed to be a repricing under the rules of any Stock Exchange on which the Stock is listed.

3.5 No Liability.

No member of the Board or the Committee shall be liable for any action or determination made in good faith with respect to the Plan or any Award or Award Agreement.

3.6 Registration; Share Certificates.

Notwithstanding any provision of the Plan to the contrary, the ownership of the shares of Stock issued under the Plan may be evidenced in such a manner as the Committee, in its sole discretion, deems appropriate, including by book-entry or direct registration (including transaction advices) or the issuance of one or more share certificates.

4. STOCK SUBJECT TO THE PLAN

4.1 Number of Shares of Stock Available for Awards.

Subject to such additional shares of Stock as shall be available for issuance under the Plan pursuant to Section 4.2, and subject to adjustment pursuant to Article 13, the maximum number of shares of Stock available for issuance under the Plan shall be ninety five thousand (95,000) shares of Stock (which shall include, for the avoidance of doubt and for the sake of clarity, shares of Series A Common Stock of VGLNG issued pursuant to the exercise of options granted under the Predecessor Plan). Such shares of Stock may be authorized and unissued shares of Stock or treasury shares of Stock or any combination of the foregoing, as may be determined from time to time by the Board or by the Committee. Any or all of the shares of Stock available for issuance under the Plan shall be available for issuance pursuant to the Incentive Stock Options.

4.2 Adjustments in Authorized Shares of Stock.

In connection with mergers, reorganizations, separations, or other transactions to which Code Section 424(a) applies, the Committee shall have the right to cause the Company to assume awards previously granted under a compensatory plan by another business entity that is a party to such transaction and to substitute Awards under the Plan for such awards. The number of shares of Stock available for issuance under the Plan pursuant to Section 4.1 shall be increased by the number of shares of Stock subject to any such assumed awards and substitute Awards. Shares available for issuance under a shareholder-approved plan of a business entity that is a party to such transaction (as appropriately adjusted, if necessary, to reflect such transaction) may be used for Awards under the Plan and shall not reduce the number of shares of Stock otherwise available for issuance under the Plan, subject to applicable rules of any Stock Exchange on which the Stock is listed.

 

10


4.3 Share Usage.

Shares of Stock covered by an Award shall be counted as used as of the Grant Date for purposes of calculating the number of shares of Stock available for issuance under Section 4.1. Any shares of Stock that are subject to Awards will be counted against the share issuance limit set forth in Section 4.1 as one share of Stock for every one share of Stock subject to an Award. If any shares covered by an Award are not purchased or are forfeited or expire, or if an Award otherwise terminates without delivery of any Stock subject thereto or is settled in cash in lieu of shares, then the number of shares of Stock counted against the aggregate number of shares available under the Plan with respect to such Award shall, to the extent of any such forfeiture, termination, or expiration again be available for making Awards under the Plan. The number of shares of Stock available for issuance under the Plan will not be increased by the number of shares of Stock (a) tendered or withheld or subject to an Award granted under the Plan surrendered in connection with the purchase of shares of Stock upon exercise of an Option as provided in Section 9.2, (b) deducted or delivered from payment of an Award granted under the Plan in connection with the Company’s tax withholding obligations as provided in Section 14.4, or (c) purchased by the Company with proceeds from Option exercises.

5. TERM; AMENDMENT AND TERMINATION

5.1 Term.

The Plan shall terminate automatically twenty (20) years after the Effective Date and may be terminated on any earlier date as provided in Section 5.2.

5.2 Amendment and Termination.

The Board may, at any time and from time to time, amend, suspend or terminate the Plan as to any shares of Stock as to which Awards have not been made. The effectiveness of any amendment to the Plan shall be contingent on approval of such amendment by the Company’s stockholders to the extent provided by the Board or required by Applicable Laws (including the rules of any Stock Exchange on which the Stock is then listed). No amendment, suspension or termination of the Plan shall impair rights or obligations under any Award theretofore made under the Plan without the consent of the Grantee thereof.

6. AWARD ELIGIBILITY AND LIMITATIONS

6.1 Eligible Grantees.

Subject to this Article 6, Awards may be made under the Plan to (a) any Service Provider, as the Committee shall determine and designate from time to time and (b) any other individual whose participation in the Plan is determined to be in the best interests of the Company by the Committee.

6.2 Stand-Alone, Additional and Substitute Awards.

Subject to Section 3.4, Awards granted under the Plan may, in the discretion of the Committee, be granted either alone or in addition to, or in substitution or exchange for, (a) any other Award, (b) any award granted under another plan of the Company, an Affiliate, or any business entity that has been a party to a transaction with the Company or an Affiliate, or (c) any other right of a Grantee to receive payment from the Company or an Affiliate. Such additional and substitute or exchange Awards may be granted at any time. If an Award is granted in substitution or exchange for another Award, or for an award granted under another plan of the Company, an Affiliate, or any business entity that has been a party to a transaction with the Company or an Affiliate, the Committee shall require the surrender of such other Award or award under such other plan in consideration for the grant of such substitute or exchange Award. In addition, Awards may be granted in lieu of cash compensation,

 

11


including in lieu of cash payments under other plans of the Company or an Affiliate. Notwithstanding Section 8.1, but subject to Section 3.4, the Option Price of an Option that is a Substitute Award may be less than one hundred percent (100%) of the Fair Market Value of a share of Stock on the original Grant Date; provided that such Option Price is determined in accordance with the principles of Code Section 424 for any Incentive Stock Option and consistent with Code Section 409A for any other Option.

7. AWARD AGREEMENT

Each Award granted pursuant to the Plan shall be evidenced by an Award Agreement, which shall be in such form or forms as the Committee shall from time to time determine. Award Agreements employed under the Plan from time to time or at the same time need not contain similar provisions but shall be consistent with the terms of the Plan. Each Award Agreement shall specify whether the Options that are subject to the Award Agreement are intended to be Non-qualified Stock Options or Incentive Stock Options, and, in the absence of such specification, such Options shall be deemed to constitute Non-qualified Stock Options.

8. TERMS AND CONDITIONS OF OPTIONS

8.1 Option Price.

The Option Price of each Option shall be fixed by the Committee and stated in the Award Agreement evidencing such Option. Except in the case of Substitute Awards, the Option Price of each Option shall be at least the Fair Market Value of one (1) share of Stock on the Grant Date; provided that in the event that a Grantee is a Ten Percent Stockholder, the Option Price of an Option granted to such Grantee that is intended to be an Incentive Stock Option shall be not less than one hundred ten percent (110%) of the Fair Market Value of one (1) share of Stock on the Grant Date; provided, further, that, to the extent permitted by Applicable Law, an Award to a non-U.S. Grantee may be made with an Option Price that is less than the Fair Market Value of one (1) share of Stock on the Grant Date. In no case shall the Option Price of any Option be less than the par value of a share of Stock.

8.2 Vesting and Exercisability.

Subject to Sections 8.3 and 13.3, each Option granted under the Plan shall become vested and/or exercisable at such times and under such conditions as shall be determined by the Committee and stated in the Award Agreement, in another agreement with the Grantee or otherwise in writing.

8.3 Term.

Each Option granted under the Plan shall terminate, and all rights to purchase shares of Stock thereunder shall cease, upon the expiration of ten (10) years from the Grant Date of such Option, or under such circumstances and on such date prior thereto as is set forth in the Plan or as may be fixed by the Committee and stated in the Award Agreement relating to such Option; provided that in the event that the Grantee is a Ten Percent Stockholder, an Option granted to such Grantee that is intended to be an Incentive Stock Option shall not be exercisable after the expiration of five (5) years from its Grant Date; and provided, further, that, to the extent deemed necessary or appropriate by the Committee to reflect differences in local law, tax policy, or custom with respect to any Option granted to a Grantee who is a foreign national or is a natural Person who is employed outside the United States, such Option may terminate, and all rights to purchase shares of Stock thereunder may cease, upon the expiration of such period longer than ten (10) years from the Grant Date of such Option as the Committee shall determine.

 

12


8.4 Termination of Service.

Each Award Agreement with respect to the grant of an Option shall set forth the extent to which the Grantee thereof, if at all, shall have the right to exercise such Option following termination of such Grantee’s Service. Such provisions shall be determined in the sole discretion of the Committee, need not be uniform among all Options issued pursuant to the Plan, and may reflect distinctions based on the reasons for termination of Service. Notwithstanding the foregoing, unless expressly provided otherwise in an applicable Award Agreement, vested Options must be exercised no later than the earliest of: (a) the one (1)-year anniversary of the Service Provider ceasing to provide Services, (b) if the termination of Service occurs after an IPO, the sixtieth (60th)-day after the Service Provider’s termination of Service (or, if later, the sixtieth (60th)-day following expiration of any underwriters’ lock up applicable to the Stock subject to the vested Option), and (c) the end of the term of the vested Option. Vested Options that are unexercised as of the close of the exercise period described in the prior sentence shall expire pursuant to this Section 8.4.

8.5 Limitations on Exercise of Option.

Notwithstanding any other provision of the Plan, in no event may any Option be exercised, in whole or in part, after the occurrence of an event referred to in Article 13 which results in the termination of such Option.

8.6 Method of Exercise.

Subject to the terms of Article 9 and Section 14.4, an Option that is exercisable may be exercised by the Grantee’s delivery to the Company or its designee or agent of notice of exercise on any business day, at the Company’s principal office or the office of such designee or agent, on the form specified by the Company and in accordance with any additional procedures specified by the Committee. Such notice shall specify the number of shares of Stock with respect to which such Option is being exercised and shall be accompanied by payment in full of the Option Price of the shares of Stock for which such Option is being exercised plus the amount (if any) of federal and/or other taxes which the Company may, in its judgment, be required to withhold with respect to the exercise of such Option.

8.7 Rights of Holders of Options.

Unless otherwise stated in the applicable Award Agreement, a Grantee or other Person holding or exercising an Option shall have none of the rights of a stockholder of the Company (for example, the right to receive cash or dividend payments or distributions attributable to the shares of Stock subject to such Option, to direct the voting of the shares of Stock subject to such Option, or to receive notice of any meeting of the Company’s stockholders) until the shares of Stock subject thereto are fully paid and issued to such Grantee or other Person. Except as provided in Article 13, no adjustment shall be made for dividends, distributions or other rights with respect to any shares of Stock subject to an Option for which the record date is prior to the date of issuance of such shares of Stock.

8.8 Delivery of Stock.

Promptly after the exercise of an Option by a Grantee and the payment in full of the Option Price with respect thereto, such Grantee shall be entitled to receive such evidence of such Grantee’s ownership of the shares of Stock subject to such Option as shall be consistent with Section 3.6.

 

13


8.9 Transferability of Options.

Except as provided in Section 8.10, during the lifetime of a Grantee of an Option, only such Grantee (or, in the event of such Grantee’s legal incapacity or incompetency, such Grantee’s guardian or legal representative) may exercise such Option. Except as provided in Section 8.10, no Option shall be assignable or transferable by the Grantee to whom it is granted, other than by will or the laws of descent and distribution.

8.10 Family Transfers.

If authorized in the applicable Award Agreement and by the Committee, in its sole discretion, a Grantee may transfer, not for value, all or part of an Option which is not an Incentive Stock Option to any Family Member. For the purpose of this Section 8.10, a transfer “not for value” is a transfer which is (a) a gift, (b) a transfer under a domestic relations order in settlement of marital property rights or (c) unless Applicable Laws do not permit such transfer, a transfer to an entity in which more than fifty percent (50%) of the voting interests are owned by Family Members (and/or the Grantee) in exchange for an interest in such entity. Following a transfer under this Section 8.10, any such Option shall continue to be subject to the same terms and conditions as were applicable immediately prior to such transfer, and the shares of Stock acquired pursuant to such Option shall be subject to the same restrictions with respect to transfers of such shares of Stock as would have applied to the Grantee thereof. Subsequent transfers of transferred Options shall be prohibited except to Family Members of the original Grantee in accordance with this Section 8.10 or by will or the laws of descent and distribution. The provisions of Section 8.4 relating to termination of Service shall continue to be applied with respect to the original Grantee of the Option, following which such Option shall be exercisable by the transferee only to the extent, and for the periods specified, in Section 8.4.

8.11 Limitations on Incentive Stock Options.

An Option shall constitute an Incentive Stock Option only (a) if the Grantee of such Option is an Employee of the Company or any corporate Subsidiary, (b) to the extent specifically provided in the related Award Agreement and (c) to the extent that the aggregate Fair Market Value (determined at the time such Option is granted) of the shares of Stock with respect to which all Incentive Stock Options held by such Grantee become exercisable for the first time during any calendar year (under the Plan and all other plans of the Company and its Affiliates) does not exceed one hundred thousand dollars ($100,000). Except to the extent provided in the regulations under Code Section 422, this limitation shall be applied by taking Options into account in the order in which they were granted.

8.12 Notice of Disqualifying Disposition.

If any Grantee shall make any disposition of shares of Stock issued pursuant to the exercise of an Incentive Stock Option under the circumstances provided in Code Section 421(b) (relating to certain disqualifying dispositions), such Grantee shall notify the Company of such disposition within ten (10) days thereof.

 

14


9. FORM OF PAYMENT FOR OPTIONS

9.1 General Rule.

Payment of the Option Price for the shares of Stock purchased pursuant to the exercise of an Option shall be made in cash or in cash equivalents acceptable to the Company.

9.2 Surrender of Shares of Stock.

To the extent that the applicable Award Agreement so provides, payment of the Option Price for shares of Stock purchased pursuant to the exercise of an Option may be made all or in part through the tender or attestation to the Company of shares of Stock, which shall be valued, for purposes of determining the extent to which such Option Price has been paid thereby, at their Fair Market Value on the date of such tender or attestation.

9.3 Cashless Exercise.

To the extent permitted by Applicable Laws and to the extent the Award Agreement so provides, payment of the Option Price for shares of Stock purchased pursuant to the exercise of an Option may be made all or in part by delivery (on a form acceptable to the Committee) of an irrevocable direction to a licensed securities broker acceptable to the Company to sell shares of Stock and to deliver all or part of the proceeds of such sale to the Company in payment of such Option Price and any withholding taxes described in Section 14.4, or, with the consent of the Company, by issuing the number of shares of Stock equal in value to the difference between such Option Price and the Fair Market Value of the shares of Stock subject to the portion of such Option being exercised.

9.4 Other Forms of Payment.

To the extent the Award Agreement so provides and/or unless otherwise specified in an Award Agreement, payment of the Option Price for shares of Stock purchased pursuant to exercise of an Option may be made in any other form that is consistent with Applicable Laws, including by withholding shares of Stock that would otherwise vest or be issuable in an amount equal to the Option Price and the required tax withholding amount.

10. RESTRICTIONS ON TRANSFER OF SHARES OF STOCK

10.1 Right of First Refusal.

Any shares of Stock acquired by, or delivered or issued to, the Grantee under the Plan may be subject to a right of first refusal of the Company as the Board may determine, consistent with Applicable Law. Unless otherwise provided in the applicable Award Agreement, prior to the time when the Stock is listed on a Stock Exchange or is publicly traded on a Securities Market, no Grantee shall sell, pledge, assign, gift, transfer, or otherwise dispose of any Stock acquired pursuant an Option to any Person without first offering such Stock to the Company for purchase on the same terms and conditions as those offered the proposed transferee. The Company may assign its right of first refusal in whole or in part, to (a) any holder of Stock or other securities of the Company, (b) any of its Affiliates, or (c) any other Person that the Board determines has a sufficient relationship with or interest in the Company. The Company shall give reasonable written notice to the applicable Grantee of any such assignment of its rights. Unless otherwise provided in the applicable Award Agreement, prior to the time when the Stock is listed on a Stock Exchange or is publicly traded on a Securities Market, these

 

15


restrictions shall apply to any Person to whom Stock that was originally acquired pursuant to an Option is sold, pledged, assigned, bequeathed, gifted, transferred, or otherwise disposed of, without regard to the number of such subsequent transferees or the manner in which they acquire the Stock, but these restrictions shall not apply to a transfer of Stock that occurs as a result of a Grantee’s death or the death of any subsequent transferee (but shall apply to the executor, the administrator or personal representative, the estate, and the legatees, beneficiaries, and assigns thereof). Furthermore, unless otherwise provided in the applicable Award Agreement, if a Grantee’s death occurs prior to the time when the Stock is listed on a Stock Exchange or is publicly traded on a Securities Market, the Company shall have the right to repurchase any Stock acquired pursuant to an Option from such Grantee’s beneficiary or estate, as applicable, at any time during the one hundred eighty (180)-day period following such Grantee’s death. The purchase price in all such circumstances shall be the aggregate Fair Market Value of the applicable shares of Stock on the repurchase date.

10.2 Repurchase and Other Rights.

Stock issued upon exercise of an Option may be subject to such right of repurchase upon termination of Service or other transfer restrictions as the Board may determine, consistent with Applicable Law. Any additional restrictions shall be set forth in an Award Agreement or in the Shareholders’ Agreement.

10.3 Market Stand-Off.

In connection with any underwritten public offering by the Company of its equity securities pursuant to an effective registration statement filed under the Securities Act, including the Company’s IPO, no Grantee shall be permitted to sell, make any short sale of, loan, hypothecate, pledge, grant any option for the purchase of, or otherwise dispose or transfer for value or agree to engage in any of the foregoing transactions with respect to any Stock without the prior written consent of the Company or its underwriters, for such period of time after the effective date of such registration statement as may be requested by the Company or the underwriters, which is expected not to exceed one hundred eighty (180) days in length, but may be longer if required by the Company’s underwriters.

10.4 Legend.

In order to enforce the restrictions imposed upon shares of Stock under this Plan or as provided in an Award Agreement, the Board may cause a legend or legends to be placed on any certificate representing shares issued pursuant to this Plan that complies with the applicable securities laws.

11. PARACHUTE LIMITATIONS

If any Grantee is a Disqualified Individual, then, notwithstanding any other provision of the Plan or of any Other Agreement, and notwithstanding any Benefit Arrangement, any right of the Grantee to any exercise, vesting, payment, or benefit under the Plan shall be reduced or eliminated:

(a) to the extent that such right to exercise, vesting, payment, or benefit, taking into account all other rights, payments, or benefits to or for the Grantee under the Plan, all Other Agreements, and all Benefit Arrangements, would cause any exercise, vesting, payment, or benefit to the Grantee under the Plan to be considered a Parachute Payment; and

 

16


(b) if, as a result of receiving such Parachute Payment, the aggregate after-tax amounts received by the Grantee from the Company under the Plan, all Other Agreements, and all Benefit Arrangements would be less than the maximum after-tax amount that could be received by the Grantee without causing any such payment or benefit to be considered a Parachute Payment.

The Company shall accomplish such reduction by first reducing or eliminating any cash payments (with the payments to be made furthest in the future being reduced first), then by reducing or eliminating any accelerated vesting of Options, then by reducing or eliminating any other remaining Parachute Payments.

12. REQUIREMENTS OF LAW

12.1 General.

The Company shall not be required to offer, sell or issue any shares of Stock under any Award, whether pursuant to the exercise of an Option or otherwise, if the offer, sale or issuance of such shares of Stock would constitute a violation by the Grantee, the Company or an Affiliate, or any other Person, of any provision of Applicable Laws, including any federal or state securities laws or regulations. If at any time the Company shall determine, in its discretion, that the listing, registration or qualification of any shares of Stock subject to an Award upon any securities exchange or under any governmental regulatory body is necessary or desirable as a condition of, or in connection with, the offering, issuance, sale or purchase of shares of Stock in connection with any Award, no shares of Stock may be offered, issued or sold to the Grantee or any other Person under such Award, whether pursuant to the exercise of an Option or otherwise, unless such listing, registration or qualification shall have been effected or obtained free of any conditions not acceptable to the Company, and any delay caused thereby shall in no way affect the date of termination of such Award. Without limiting the generality of the foregoing, upon the exercise of any Option that may be settled in shares of Stock, unless a registration statement under the Securities Act is in effect with respect to the shares of Stock subject to such Award, the Company shall not be required to offer, sell or issue such shares of Stock unless the Committee shall have received evidence satisfactory to it that the Grantee or any other Person exercising such Option may acquire such shares of Stock pursuant to an exemption from registration under the Securities Act. Any determination in this connection by the Committee shall be final, binding, and conclusive. The Company may register, but shall in no event be obligated to register, any shares of Stock or other securities issuable pursuant to the Plan pursuant to the Securities Act. The Company shall not be obligated to take any affirmative action in order to cause the exercise of an Option or the issuance of shares of Stock or other securities issuable pursuant to the Plan or any Award to comply with any Applicable Laws. As to any jurisdiction that expressly imposes the requirement that an Option that may be settled in shares of Stock shall not be exercisable until the shares of Stock subject to such Option are registered under the securities laws thereof or are exempt from such registration, the exercise of such Option under circumstances in which the laws of such jurisdiction apply shall be deemed conditioned upon the effectiveness of such registration or the availability of such an exemption.

12.2 Rule 16b-3.

During any time when the Company has a class of equity security registered under Section 12 of the Exchange Act, it is the intention of the Company that Awards pursuant to the Plan and the exercise of Options granted hereunder that would otherwise be subject to Section 16(b) of the Exchange Act shall qualify for the exemption provided by Rule 16b-3 under the Exchange Act. To the extent that any provision of the Plan or action by the Committee does not comply with the requirements of such Rule 16b-3, such provision or action shall be deemed inoperative with respect to such Awards

 

17


to the extent permitted by Applicable Laws and deemed advisable by the Committee, and shall not affect the validity of the Plan. In the event that such Rule 16b-3 is revised or replaced, the Board may exercise its discretion to modify the Plan in any respect necessary or advisable in its judgment to satisfy the requirements of, or to permit the Company to avail itself of the benefits of, the revised exemption or its replacement.

13. EFFECT OF CHANGES IN CAPITALIZATION

13.1 Changes in Stock.

If the number of outstanding shares of Stock is increased or decreased or the shares of Stock are changed into or exchanged for a different number of shares or kind of capital stock or other securities of the Company on account of any recapitalization, reclassification, stock split, reverse stock split, spin-off, combination of stock, exchange of stock, stock dividend or other distribution payable in capital stock, or other increase or decrease in shares of Stock effected without receipt of consideration by the Company occurring after the Effective Date, the number and kinds of shares of stock for which grants of Options may be made under the Plan shall be adjusted proportionately and accordingly by the Committee. In addition, the number and kind of shares of stock for which Awards are outstanding shall be adjusted proportionately and accordingly by the Committee so that the proportionate interest of the Grantee therein immediately following such event shall, to the extent practicable, be the same as immediately before such event. Any such adjustment in outstanding Options shall not change the aggregate Option Price payable with respect to shares that are subject to the unexercised portion of such outstanding Options, but shall include a corresponding proportionate adjustment in the per share Option Price, as the case may be. The conversion of any convertible securities of the Company shall not be treated as an increase in shares effected without receipt of consideration. Notwithstanding the foregoing, in the event of any distribution to the Company’s stockholders of securities of any other entity or other assets (including an extraordinary dividend, but excluding a non-extraordinary dividend, declared and paid by the Company) without receipt of consideration by the Company, the Board or the Committee constituted pursuant to Section 3.1.2 shall, in such manner as the Board or the Committee deems appropriate, adjust (a) the number and kind of shares of stock subject to outstanding Awards and/or (b) the aggregate and per share Option Price of outstanding Options as required to reflect such distribution.

13.2 Reorganization in Which the Company Is the Surviving Entity Which Does not Constitute a Change in Control.

Subject to Section 13.3, if the Company shall be the surviving entity in any reorganization, merger or consolidation of the Company with one or more other entities which does not constitute a Change in Control, any Option theretofore granted pursuant to the Plan shall pertain to and apply to the securities to which a holder of the number of shares of Stock subject to such Option would have been entitled immediately following such reorganization, merger or consolidation, with a corresponding proportionate adjustment of the per share Option Price so that the aggregate Option Price thereafter shall be the same as the aggregate Option Price of the shares of Stock remaining subject to the Option as in effect immediately prior to such reorganization, merger, or consolidation. Subject to any contrary language in an Award Agreement or in another agreement with the Grantee, or otherwise set forth in writing, any restrictions applicable to such Award shall apply as well to any replacement shares received by the Grantee as a result of such reorganization, merger or consolidation.

 

18


13.3 Change in Control in which Awards are not Assumed.

Except as otherwise provided in the applicable Award Agreement or in another agreement with the Grantee, or as otherwise set forth in writing, upon the occurrence of a Change in Control in which outstanding Options are not being assumed or continued, either of the following two actions shall be taken with respect to such Award, to the extent not assumed or continued:

(a) fifteen (15) days prior to the scheduled consummation of such Change in Control, all Options outstanding hereunder shall become immediately exercisable and shall remain exercisable for a period of fifteen (15) days, which exercise shall be effective upon such consummation; and/or

(b) the Committee may elect, in its sole discretion, to cancel any outstanding Options and pay or deliver, or cause to be paid or delivered, to the holder thereof an amount in cash or securities having a value (as determined by the Committee acting in good faith) equal to the product of the number of shares of Stock subject to such Options multiplied by the amount, if any, by which (x) the formula or fixed price per share paid to holders of shares of Stock pursuant to such transaction exceeds (y) the Option Price applicable to such Options.

With respect to the Company’s establishment of an exercise window, (a) any exercise of an Option during the fifteen (15)-day period referred to above shall be conditioned upon the consummation of the applicable Change in Control and shall be effective only immediately before the consummation thereof, and (b) upon consummation of any Change in Control, the Plan and all outstanding but unexercised Options shall terminate. The Committee shall send notice of an event that shall result in such a termination to all natural Persons and entities who hold Options not later than the time at which the Company gives notice thereof to its stockholders.

13.4 Change in Control in which Awards are Assumed.

Except as otherwise provided in the applicable Award Agreement or in another agreement with the Grantee, or as otherwise set forth in writing, upon the occurrence of a Change in Control in which outstanding Options are being assumed or continued, the following provisions shall apply to such Options, to the extent assumed or continued:

The Plan and the Options granted under the Plan shall continue in the manner and under the terms so provided in the event of any Change in Control to the extent that provision is made in writing in connection with such Change in Control for the assumption or continuation of such Options, or for the substitution for such Options of new stock options relating to the stock of a successor entity, or a parent or subsidiary thereof, with appropriate adjustments as to the number of shares (disregarding any consideration that is not common stock) and option exercise prices.

13.5 Adjustments

Adjustments under this Article 13 related to shares of Stock or other securities of the Company shall be made by the Committee, whose determination in that respect shall be final, binding and conclusive. No fractional shares or other securities shall be issued pursuant to any such adjustment, and any fractions resulting from any such adjustment shall be eliminated in each case by rounding downward to the nearest whole share. The Committee may provide in the applicable Award Agreement at the time of grant, in another agreement with the Grantee, or otherwise in writing at any time thereafter with the consent of the Grantee, for different provisions to apply to an Award in place of those provided in Sections 13.1, 13.2, 13.3 and 13.4. This Article 13 shall not limit the Committee’s ability to provide for alternative treatment of Awards outstanding under the Plan in the event of a change in control event involving the Company that is not a Change in Control.

 

19


13.6 No Limitations on Company.

The making of Awards pursuant to the Plan shall not affect or limit in any way the right or power of the Company to make adjustments, reclassifications, reorganizations, or changes of its capital or business structure or to merge, consolidate, dissolve, or liquidate, or to sell or transfer all or any part of its business or assets (including all or any part of the business or assets of any Subsidiary or other Affiliate) or engage in any other transaction or activity.

14. GENERAL PROVISIONS

14.1 Shareholders’ Agreement

As a condition precedent to an Award, the exercise of an Option, or to the delivery of shares of Stock issued pursuant to any Option, the Grantee or his Family Member, as the case may be, shall become a party to the Shareholders’ Agreement, in such forms as the Board may determine from time to time. Any shares of Stock acquired pursuant to the Plan shall be subject in all cases to the provisions of the Shareholders’ Agreement. In the event of any inconsistency between the Plan, an Award Agreement and the Shareholders’ Agreement, the provisions of the Shareholders’ Agreement shall control.

14.2 Disclaimer of Rights.

No provision in the Plan or in any Award or Award Agreement shall be construed to confer upon any individual the right to remain in the employ or Service of the Company or an Affiliate, or to interfere in any way with any contractual or other right or authority of the Company or an Affiliate either to increase or decrease the compensation or other payments to any natural Person or entity at any time, or to terminate any employment or other relationship between any natural Person or entity and the Company or an Affiliate. In addition, notwithstanding anything contained in the Plan to the contrary, unless otherwise stated in the applicable Award Agreement, in another agreement with the Grantee, or otherwise in writing, no Award granted under the Plan shall be affected by any change of duties or position of the Grantee thereof, so long as such Grantee continues to provide Service. The obligation of the Company to pay any benefits pursuant to the Plan shall be interpreted as a contractual obligation to pay only those amounts provided herein, in the manner and under the conditions prescribed herein. The Plan and Awards shall in no way be interpreted to require the Company to transfer any amounts to a third-party trustee or otherwise hold any amounts in trust or escrow for payment to any Grantee or beneficiary under the terms of the Plan.

14.3 Nonexclusivity of the Plan.

Neither the adoption of the Plan nor the submission of the Plan to the stockholders of the Company for approval shall be construed as creating any limitations upon the right and authority of the Board to adopt such other incentive compensation arrangements (which arrangements may be applicable either generally to a class or classes of individuals or specifically to a particular individual or particular individuals) as the Board in its discretion determines desirable.

 

20


14.4 Withholding Taxes.

The Company or an Affiliate, as the case may be, shall have the right to deduct from payments of any kind otherwise due to a Grantee any federal, state, or local taxes of any kind required by law to be withheld with respect to the vesting of or other lapse of restrictions applicable to an Award or upon the issuance of any shares of Stock upon the exercise of an Option. At the time of such vesting, lapse, or exercise, the Grantee shall pay in cash to the Company or an Affiliate, as the case may be, any amount that the Company or such Affiliate may reasonably determine to be necessary to satisfy such withholding obligation. Subject to the prior approval of the Company or an Affiliate, which may be withheld by the Company or such Affiliate, as the case may be, in its sole discretion, the Grantee may elect to satisfy such withholding obligation, in whole or in part, (a) by causing the Company or such Affiliate to withhold shares of Stock otherwise issuable to the Grantee or (b) by delivering to the Company or such Affiliate shares of Stock already owned by the Grantee. The shares of Stock so withheld or delivered shall have an aggregate Fair Market Value equal to such withholding obligation. The Fair Market Value of the shares of Stock used to satisfy such withholding obligation shall be determined by the Company or such Affiliate as of the date on which the amount of tax to be withheld is to be determined. A Grantee who has made an election pursuant to this Section 14.4 may satisfy such Grantee’s withholding obligation only with shares of Stock that are not subject to any repurchase, forfeiture, unfulfilled vesting, or other similar requirements. The maximum number of shares of Stock that may be withheld from any Award to satisfy any federal, state or local tax withholding requirements upon the exercise, vesting, or lapse of restrictions applicable to any Award or payment of shares of Stock pursuant to such Award, as applicable, may not exceed such number of shares of Stock having a Fair Market Value equal to the minimum statutory amount required by the Company or the applicable Affiliate to be withheld and paid to any such federal, state or local taxing authority with respect to such exercise, vesting, lapse of restrictions, or payment of shares of Stock.

14.5 Captions.

The use of captions in the Plan or any Award Agreement is for convenience of reference only and shall not affect the meaning of any provision of the Plan or such Award Agreement.

14.6 Construction.

Unless the context otherwise requires, all references in the Plan to “including” shall mean “including without limitation.”

14.7 Other Provisions.

Each Award granted under the Plan may contain such other terms and conditions not inconsistent with the Plan as may be determined by the Committee, in its sole discretion. Furthermore, following an IPO, any sales of the Company’s Stock made by certain Grantees designated by the Company (the “Designated Grantees”) must be executed pursuant to a pre-approved trading plan in accordance with Securities and Exchange Commission Rule 10b5-1(c) (a “10b5-1 Trading Plan”). Such 10b5-1 Trading Plan must be executed with a broker designated by the Company, unless the Designated Grantee has received written authorization from the Company’s General Counsel to use a different broker.

14.8 Number and Gender.

With respect to words used in the Plan, the singular form shall include the plural form and the masculine gender shall include the feminine gender, as the context requires.

 

21


14.9 Severability.

If any provision of the Plan or any Award Agreement shall be determined to be illegal or unenforceable by any court of law in any jurisdiction, the remaining provisions hereof and thereof shall be severable and enforceable in accordance with their terms, and all provisions shall remain enforceable in any other jurisdiction.

14.10 Governing Law.

The validity and construction of the Plan and the instruments evidencing the Awards hereunder shall be governed by, and construed and interpreted in accordance with, the laws of the State of New York, other than any conflicts or choice of law rule or principle that might otherwise refer construction or interpretation of the Plan and the instruments evidencing the Awards granted hereunder to the substantive laws of any other jurisdiction.

14.11 Section 409A of the Code.

The Plan is intended to comply with Code Section 409A to the extent subject thereto, and, accordingly, to the maximum extent permitted, the Plan will be interpreted and administered to be in compliance with Code Section 409A. Any payments described in the Plan that are due within the Short-Term Deferral Period will not be treated as deferred compensation unless Applicable Laws require otherwise. Notwithstanding anything to the contrary in the Plan, to the extent required to avoid accelerated taxation and tax penalties under Code Section 409A, amounts that would otherwise be payable and benefits that would otherwise be provided pursuant to the Plan during the six-month period immediately following the Grantee’s Separation from Service will instead be paid on the first payroll date after the six-month anniversary of the Grantee’s Separation from Service (or the Grantee’s death, if earlier).

Notwithstanding the foregoing, neither the Company nor the Committee will have any obligation to take any action to prevent the assessment of any excise tax or penalty on any Grantee under Code Section 409A and neither the Company nor the Committee will have any liability to any Grantee for such tax or penalty.

 

22


To record the amendment of the Plan by the Board as of November 14, 2024, the Company has caused its authorized officer to execute the Plan.

 

VENTURE GLOBAL, INC.

By:

   

Name:

 

Keith Larson

Title:

 

General Counsel and Secretary

Exhibit 10.102

FORM OF VENTURE GLOBAL HOLDINGS, INC.

2023 STOCK OPTION PLAN

NON-QUALIFIED STOCK OPTION AGREEMENT

Venture Global Holdings, Inc., a Delaware corporation (the “Company”), hereby grants a non-qualified stock option to purchase the number of shares of Class A Common Stock of the Company, par value $0.01 per share (the “Common Shares”), to the Grantee named below. Additional terms and conditions of the grant are set forth on this cover sheet and in the attached Non-qualified Stock Option Agreement (together, the “Agreement”), and in the Company’s 2023 Stock Option Plan (as amended, the “Plan”). This Option is expressly made contingent on the Grantee’s agreement to and execution of the Restrictive Covenant Agreement between the Company and the Grantee on or prior to the Grant Date (below), and the Agreement shall be void unless such Restrictive Covenant Agreement is executed by the Grantee on or prior to the Grant Date.

 

Grantee Name:     
Grant Date:     
Number of Common Shares:     
Option Price per Common Share:     
Vesting Start Date:     
Vesting Schedule:    The Option shall vest and become exercisable with respect to the underlying Common Shares in sixteen (16) equal installments (rounded down to the nearest whole share, except for the last vesting installment) on each three (3) month anniversary of the Vesting Start Date over a period of four (4) years beginning on the Vesting Start Date, subject to the Grantee’s continued Service through each vesting date; provided however that the sixteenth (16th) installment shall vest on [grant date plus 4 years], subject to the Grantee’s continued Service through such date.


Expiration Date:    Date that is 10 years from the Grant Date.
      

[Signature Page Follows]

 

2


By your signature below, you agree to all of the terms and conditions described in the Agreement and in the Plan, a copy of which has been provided to you. You acknowledge that you have carefully reviewed the Plan, and agree that the Plan will control in the event any provision of this Agreement is inconsistent with the Plan. You also agree to the terms and conditions of the Restrictive Covenant Agreement.

 

Grantee:         Date:    
  (Signature)      
Company:         Date:    
  (Signature)      
Title:   Authorized Signatory      

Attachment

This is not a stock certificate or a negotiable instrument.

 

3


VENTURE GLOBAL HOLDINGS, INC.

2023 STOCK OPTION PLAN

NON-QUALIFIED STOCK OPTION AGREEMENT

 

Non-qualified Stock Option    This Agreement evidences an Option grant exercisable for the number of Common Shares set forth on the cover sheet of this Agreement and subject to the vesting and other terms and conditions set forth in this Agreement and in the Plan. The Option is not intended to be an incentive stock option under Section 422 of the Code and will be interpreted accordingly.
Vesting and Forfeiture    The Option will vest in accordance with the Vesting Schedule set forth on the Cover Sheet, subject to your continued Service through each vesting date. If Service is terminated for any reason the unvested portion of the Option will be forfeited and, in the case of your termination of Service by the Company for Cause, any portion of your Option that is vested but unexercised shall be forfeited.
Exercisability and Expiration of Option   

You may exercise the vested portion of your Option in accordance with the terms of this Agreement and the Plan prior to the Expiration Date, provided, however, that prior to the date of a consummation of a Change in Control or IPO, such exercise may only be effected with the consent of the Committee. The vested portion of your Option may not be exercised following the Expiration Date set forth on the cover sheet of this Agreement. Your Option will expire on such Expiration Date.

 

Exercisability of Vested Options Following Termination Other than For Cause. If your Service is terminated for any reason, other than a termination by the Company for Cause, notwithstanding the foregoing, the vested portion of your Option will expire as follows:

 

a.   If your termination is on account of your resignation or termination by the Company without Cause, the vested portion of your Option will expire on the earliest of: (i) the one (1)-year anniversary of the date your Service terminates, (ii) if such termination occurs on or after the Company’s IPO, sixty (60) days from the date your Service terminates (or, if later, sixty (60) days following the expiration of any underwriters’ lock-up applicable to the Common Shares covered by the vested portion of your Option), and (iii) the Expiration Date; and

 

4


  

b.  If your termination is on account of your death or Disability, the vested portion of your Option will expire on the earliest to occur of: (i) the two (2)-year anniversary of the date your Service terminates; (ii) the one (1)-year anniversary of the Company’s IPO (or, if later, sixty (60) days following the expiration of any underwriters’ lock-up applicable to the Common Shares covered by the vested portion of your Option); and (iii) the Expiration Date.

 

Forfeiture of Entire Option for Termination for Cause. Notwithstanding the foregoing, if your Service is terminated by the Company for Cause, your Option (including vested and unvested portions) will immediately terminate and no longer be exercisable.

Leaves of Absence    For purposes of the Option, your Service does not terminate when you go on a bona fide employee leave of absence that the Company approves in writing if the terms of the leave provide for continued Service crediting or when continued Service crediting is required by Applicable Law or contract. Your Service terminates in any event when the approved leave ends unless you immediately return to active employment. The Company, in its sole discretion, determines which leave counts for this purpose and when your Service terminates as a result of a leave for all purposes under the Plan.
Notice of Exercise   

The Option may be exercised, in whole or in part, to purchase a whole number of vested Common Shares of not less than 10 shares, unless the number of vested Common Shares purchased is the total number available for purchase under the Option, by following the procedures described in the Plan and in this Agreement.

 

The Option may be exercised only in the manner set forth in this Agreement and the Plan.

 

If someone other than you exercises the Option after your death, then that person must submit documentation reasonably acceptable to the Committee verifying that the person has the legal authority to exercise the Option as your beneficiary.

Form of Payment   

When you exercise the Option, you must include payment of the Option Price indicated on the cover sheet of this Agreement for the Common Shares that you are purchasing. Payment may be made in one (or a combination) of the following forms:

 

a.   Cash, your personal check, a cashier’s check, a money order or another cash equivalent acceptable to the Committee.

 

b.  To the extent a public market exists for the Common Shares, as determined by the Committee, delivery (on a form prescribed or accepted by the Committee) of an irrevocable direction to a licensed securities broker acceptable to the Committee to sell the Common Shares subject to the Option and to deliver all or part of the sale proceeds to the Company in payment of the aggregate Option Price and any withholding taxes.

 

5


  

c.   Subject to the consent of the Committee, Common Shares that you already own or that are subject to the vested portion of the Option and that you surrender to the Company. The value of the Common Shares, determined on the date of exercise of the Option, will be applied to the Option Price.

Evidence of Issuance    The issuance of the Common Shares upon exercise of the Option will be evidenced in such a manner as the Committee, in its sole discretion, deems appropriate, including, without limitation, book-entry, direct registration (including transaction advices) or issuance of one or more share certificates.
Withholding    You will not be allowed to exercise the Option unless you make acceptable arrangements to pay any withholding or other taxes that may be due as a result of the Option exercise. If the Company or an Affiliate determines that any tax or withholding payment is required relating to the exercise or sale of Common Shares purchased upon exercise of the Option under Applicable Laws, the Company or an Affiliate, as the case may be, will have the right to require such payments from you or to withhold such amounts from other payments due to you from the Company or its Affiliates. Subject to the prior approval of the Company or an Affiliate, which may be withheld by the Company or such Affiliate, as the case may be, in its sole discretion, you may elect to satisfy this withholding obligation, in whole or in part, by causing the Company to withhold Common Shares otherwise issuable to you or by delivering to the Company Common Shares you already own. The Common Shares so delivered or withheld must have an aggregate Fair Market Value not exceeding the minimum amount of tax required to be withheld by Applicable Law, unless the Company has adopted Accounting Standards Update 2016-09 (“AS 2016-09”) or AS 2016-09 or a similar rule is otherwise in effect, in which case the Company instead may choose to withhold an amount of Common Shares up to the amount equal to the maximum statutory rate applicable to the Grantee. Any such withheld Common Shares may not be subject to any repurchase, forfeiture, unfulfilled vesting, or other similar requirements. The Fair Market Value of the Common Shares used to satisfy such withholding obligation shall be determined by the Company or such Affiliate as of the date on which the amount of tax to be withheld is to be determined.

 

6


Transfer of Option   

Except as provided in this section, during your lifetime only you (or in the event of your legal incapacity or incompetency, your guardian or legal representative) may exercise the Option, and the Option may not be assigned or transferred by you, other than by designation of beneficiary, will or the laws of descent and distribution. Notwithstanding the preceding, prior to an IPO (unless a public market exists for the Common Shares as determined by the Committee), any such attempted transfer to a person other than your surviving spouse or surviving issue in connection with your death shall be null and void and instead transferred to your spouse, and, if none, your children per stirpes.

 

In the event of your termination of Service, this Agreement will continue to be applied with respect to you, following which the Option will be exercisable by the eligible transferee only to the extent, and for the periods specified in this Agreement.

Market Stand-off Agreement    In connection with any underwritten public offering by the Company of its equity securities pursuant to an effective registration statement filed under the Securities Act, including the Company’s IPO, you agree not to sell, make any short sale of, loan, hypothecate, pledge, grant any option for the purchase of, or otherwise dispose or transfer for value or agree to engage in any of the foregoing transactions with respect to any Common Shares without the prior written consent of the Company or its underwriters, for such period of time after the effective date of such registration statement as may be requested by the Company or the underwriters, which is expected not to exceed 180 days in length, but may be longer if required by the Company’s underwriters.
Retention Rights    This Agreement and the grant of the Option do not give you the right to be retained by the Company or any of its Affiliates in any capacity. The Company reserves the right to terminate your Service at any time and for any reason.
Shareholder Rights    You, or your estate or heirs, have no rights as a shareholder of the Company until the Common Shares have been issued upon exercise of the Option and either a certificate evidencing the Common Shares has been issued or an appropriate entry has been made on the Company’s books. This section shall be subject in all cases to the section titled “Transfer of Option” above. No adjustments are made for dividends, distributions or other rights if the applicable record date occurs before your certificate is issued or the appropriate book entry is made, except as described in the Plan.

 

7


Applicable Law    The validity and construction of this Agreement will be governed by, and construed and interpreted in accordance with, the laws of the State of Delaware, other than any conflicts or choice of law rule or principle that might otherwise refer construction or interpretation of this Agreement to the substantive laws of any other jurisdiction.
Adjustments    If the number of outstanding Common Shares is increased or decreased or the Common Shares are changed into or exchanged for a different number of shares or kind of capital stock or other securities of the Company on account of any recapitalization, reclassification, stock split, reverse stock split, spin-off, combination of stock, exchange of stock, stock dividend or other distribution payable in capital stock, or other increase or decrease in Common Shares effected without receipt of consideration by the Company occurring after the Grant Date, the number and kind of Common Shares underlying your Option will be adjusted proportionately and accordingly by the Committee so that your proportionate interest therein immediately following such event will, to the extent practicable, be the same as immediately before such event. Any such adjustment in your Option will not change the aggregate Option Price payable with respect to Common Shares that are subject to the unexercised portion of your Option, but will include a corresponding proportionate adjustment in the per share Option Price, as the case may be.
Right of First Refusal and Right of Repurchase on Account of Death    Prior to the time when the Common Shares are listed on a Stock Exchange or are publicly traded on a Securities Market, you will not sell, pledge, assign, gift, transfer, or otherwise dispose of any Common Shares acquired pursuant to your Option to any person or entity without first offering such Common Shares to the Company for purchase on the same terms and conditions as those offered the proposed transferee. The Company may assign its right of first refusal in whole or in part, to (a) any holder of stock or other securities of the Company, (b) any of its Affiliates, or (c) any other person or entity that the Board determines has a sufficient relationship with or interest in the Company. The Company will give reasonable written notice to you of any such assignment of its rights. Prior to the time when the Common Shares are listed on a Stock Exchange or are publicly traded on a Securities Market, these restrictions apply to any person to whom Common Shares that were originally acquired pursuant to your Option are sold, pledged, assigned, bequeathed, gifted, transferred, or otherwise disposed of, without regard to the number of such subsequent transferees or the manner in which they acquire the Common Shares, but these restrictions do not apply to a transfer of Common Shares that occurs as a result of your death or the death of any subsequent transferee (but shall apply to the executor, the administrator or personal representative, the estate, and the legatees, beneficiaries, and assigns thereof). Furthermore, if your death occurs prior to the time when

 

8


   the Common Shares are listed on a Stock Exchange or are publicly traded on a Securities Market, the Company shall have the right to repurchase any Common Shares acquired pursuant to your Option from your beneficiary or estate, as applicable, at any time during the 180-day period following your death. The purchase price in all such circumstances shall be the aggregate Fair Market Value of the applicable Common Shares on the repurchase date.
Shareholders’ Agreement    As a condition to holding the Option granted under the terms of this Agreement, you agree to be bound by the Shareholders’ Agreement if, and when, you become the holder of Common Shares pursuant to exercise of the Option at a time when the Common Shares are not listed on a Stock Exchange or are not otherwise publicly traded on a Securities Market. Notwithstanding the foregoing, you will no longer be subject to the Shareholders’ Agreement following the time when the Common Shares are listed on a Stock Exchange or are publicly traded on a Securities Market. The Company represents and warrants to the Grantee that (a) it has taken the necessary corporate action and that it has the legal right to enter into this Agreement and perform all of the obligations on its part to be performed here under in accordance with the terms of this Agreement and (b) this Agreement does not conflict with the Shareholders’ Agreement.
The Plan   

The text of the Plan is incorporated into this Agreement.

 

Capitalized terms used in this Agreement but not defined will have the meaning set forth in the Plan.

 

This Agreement, the Plan, and the Restrictive Covenant Agreement, shall constitute the entire understanding between you and the Company regarding the Option. Any prior agreements, commitments or negotiations concerning the Option are superseded and replaced.

Data Privacy   

To administer the Plan, the Company may process personal data about you. This data includes, without limitation, information provided in this Agreement and any changes to such information, other appropriate personal and financial data about you, including your contact information, payroll information and any other information that the Company deems appropriate to facilitate the administration of the Plan.

 

By continuing to accept the Option, you give explicit consent to the Company to process any such personal data.

By signing this Option Agreement, you agree to all of the terms and conditions described above and in the Plan.

 

9

Exhibit 10.111

FORM OF RESTRICTIVE COVENANT AGREEMENT

This Restrictive Covenant Agreement (“Agreement”) dated [   ] (the “Effective Date”) is entered into between VENTURE GLOBAL LNG, INC. (the “Company”) and [    ]    (the “Employee”) as of the Effective Date.

The parties recognize that they are entering into this Agreement to protect the Company’s confidential and proprietary materials, goodwill, trade secrets, relationships, competitive position, and related interests. For good and valuable consideration, [including the Company stock options granted to Employee as of the Effective Date under Venture Global, Inc.’s 2023 Stock Option Plan as amended (that are contingent on Employee’s execution of this Agreement)], the sufficiency of which Employee expressly acknowledges, Employee hereby agrees as follows:

1. Restrictive Covenants. This Agreement is not intended to, and shall not be construed to, limit any legal right Employee may have to communicate information or take other action, to the extent such right as a matter of law may not be limited by private agreement, or to otherwise limit Employee’s right to engage in legally protected activities under applicable law. Subject to the foregoing, Employee agrees as follows:

(a) Confidential Information and Trade Secrets.

(i) Employee hereby agrees, during Employee’s term of employment, at all times thereafter with respect to Trade Secrets (as defined below) and for five (5) years thereafter with respect to all other Confidential Information, to treat all Confidential Information as strictly confidential, and to maintain adequate security procedures and take such additional precautions as may be prescribed from time to time by the Company to prevent the unauthorized or inadvertent disclosure, misuse, or loss of Confidential Information. Employee hereby agrees that he or she shall not, directly or indirectly, communicate, disclose, or divulge to any person, or use for his or her benefit or the benefit of any person (except as may be required in the scope of his or her duties), in any manner, any Confidential Information concerning the conduct and details of the businesses of the Company and its affiliates. For purposes of this Agreement, the term “Confidential Information” means all information, knowledge, or data relating to the Company or any of its affiliates, or to the Company’s or any such affiliate’s respective businesses and investments (whether prepared by the Employee or otherwise), learned by Employee directly or indirectly from the Company or any of its affiliates or otherwise. Confidential Information may be in any form, including spoken, written, printed, or electronic. Confidential Information includes information regarding business, administrative, or financial matters of the Company or its affiliates (including ideas, technical data, concepts, performance, equipment, configuration, Trade Secrets, budget information, business plans, strategies, methods, marketing, cost or pricing information, accounting information, information regarding debt and equity investors and potential investors, including the identity of and communications with such individuals or entities, information regarding current, former, or prospective employees or customers, including customer preferences, needs, priorities, and other customer considerations, crisis management plan policies, personnel information, contracts or terms thereof with any customer, vendor, investors or lenders, or other person or entity regarding other transactions or agreements, and any other information constituting the Company’s proprietary information). Confidential Information also includes information

 

1


the Company receives under an obligation of confidentiality to any third party and Work Product, as defined below. Confidential Information shall not include information that (A) is or becomes publicly available, other than as a result of a breach of this Agreement by Employee, or (B) was already known to and legally obtained by Employee before its disclosure to Employee during Employee’s employment by the Company.

(ii) Without in any way limiting the terms of Section 1(a)(i) above, Employee hereby agrees to hold in strict confidence all Trade Secrets that may be developed or prepared by Employee or that otherwise that come into his or her knowledge during his or her employment with the Company, and shall not directly or indirectly communicate, disclose or divulge to any person, in any manner, any Trade Secrets for so long as the information remains a Trade Secret. For purposes of this Agreement, the term “Trade Secret” means any information, including any formula, pattern, compilation, program, device, method, technique, or process, that: (A) derives independent economic value, actual or potential, from not being generally known to, and not being readily ascertainable by proper means by, other persons who can obtain economic value from its disclosure or use, and (B) is the subject of efforts that are reasonable under the circumstances to maintain its secrecy.

(iii) Upon termination of Employee’s employment for any reason, or at any other time upon request of the Company, Employee shall immediately (A) deliver to the Company the original and all copies of physical or electronic documents, records, files, recordings, media or other resources containing any Confidential Information in Employee’s possession, custody, or control; and then (B) assure that no duplicates of such Confidential Information remain in Employee’s possession, custody, or control, including on hard drives, network or “cloud” storage, or otherwise.

(iv) Employee may use or disclose Confidential Information when such use or disclosure is (A) required in the performance of Employee’s authorized employment duties to the Company; and (B) each person or entity to whom Confidential Information is disclosed, published, communicated, or made available is bound by a written obligation to protect confidentiality comparable to that in this Agreement. Employee may also use or disclose Confidential Information when authorized in writing to do so by the Company.

(v) Nothing herein shall prevent Employee from: (A) complying with a valid subpoena or other legal requirement for disclosure of Confidential Information; provided that Employee shall use good faith efforts to notify the Company promptly and in advance of disclosure if he or she believes that he or she is under a legal requirement to disclose Confidential Information otherwise protected from disclosure under this subsection and if Employee remains legally compelled to make such disclosure, Employee may only disclose that portion of the information that Employee is required to disclose and shall use best efforts to ensure that such information is afforded confidential treatment; (B) disclosing the terms and conditions of this Agreement to Employee’s spouse or tax, accounting, financial or legal advisors, so long as they agree in writing to be bound by the obligations of this subsection; (C) reporting a possible violation of law to a governmental entity or law enforcement, including making a disclosure that is protected under the whistle blower protections of applicable law or making any other disclosure that is protected under the provisions of applicable law or regulation; (D) bringing an action under Section 18 to enforce this Agreement; or (E) communicating with fellow employees or others about his or her wages, benefits or other terms of employment in the exercise of his or her statutory rights under the National Labor Relations Act or other laws. Neither the Company nor its subsidiaries or affiliates may retaliate against Employee for engaging in the specific activities set forth in this subsection.

 

2


(b) Defend Trade Secrets Act. Employee hereby acknowledges and understands that an individual may not be held liable under any criminal or civil federal or state trade secret law for disclosure of a Trade Secret: (i) made in confidence to a government official, either directly or indirectly, or to an attorney, solely for the purpose of reporting or investigating a suspected violation of law or (ii) in a complaint or other document filed in a lawsuit or other proceeding, if such filing is made under seal. Additionally, Employee further acknowledges and understands that an individual suing an employer for retaliation based on the reporting of a suspected violation of law may disclose a Trade Secret to his or her attorney and use the Trade Secret information in the court proceeding, so long as any document containing the Trade Secret is filed under seal and the individual does not disclose the Trade Secret except pursuant to court order.

(c) Non-Competition and Non-Solicitation.

(i) Employee agrees that Employee shall not, except with the Company’s express prior written consent, at all times during employment with the Company and for a period of [twelve (12)] months following termination of employment (whether terminated for any reason or no reason, by Employee or the Company), directly or indirectly (including through employment with or consulting for investment funds), engage in any business involving the development, construction or operation of any modular, mid-scale liquefied natural gas export facilities globally (the “Business”), where Employee’s engagement in the Business involves contributing Employee’s knowledge, directly or indirectly, in whole or in part, as an employee, employer, owner, operator, manager, advisor, consultant, contractor, agent, partner, director, stockholder, officer, volunteer, intern, or any other similar capacity to an entity engaged in the Business; such prohibited activity also includes activity that may require or inevitably require disclosure of Trade Secrets, proprietary information, or Confidential Information. However, this Section 1(c)(i) shall not be deemed to prohibit Employee from employment at any multinational, integrated oil and gas company that has investments in liquefied natural gas export facilities so long as Employee’s duties are not related to the Business.

(ii) The foregoing restrictions shall apply to Employee’s activities anywhere in the world, except as otherwise set forth herein. Notwithstanding the foregoing, for employees whose primary place of employment is in Louisiana, the term “Business” is limited to Businesses located in Cameron, Calcasieu, or Plaquemines parishes.

(iii) Employee agrees that Employee shall not, except with the Company’s express prior written consent, at all times during employment with the Company and for a period of six (6) months following termination of employment (whether terminated for any reason or no reason, by the Employee or the Company), own any interests in any company involved in the Business and which is competitive, directly or indirectly, with any Business carried on by the Company; provided, however, that this Section 1(c)(iii) shall not be deemed to prohibit the direct or indirect ownership by Employee of up to one percent (1%) of the outstanding equity interests of any public company.

 

3


(iv) Employee agrees that Employee shall not, except with the Company’s express prior written consent, at all times during employment with the Company and for a period of six (6) months following termination of employment (whether terminated for any reason or no reason, by the Employee or the Company), for the benefit of any entity or person (including Employee), (A) solicit, induce, or encourage any employee of the Company, or any of its affiliates, to leave the employment of the Company or its affiliates, where such employee was employed by the Company or an affiliate within the twelve (12) months prior to Employee’s termination, (B) solicit, induce, or encourage any customer, client, or independent contractor of the Company, or any of its affiliates, to cease or reduce its business with or services rendered to the Company or its affiliates, where such customer, client, or independent contractor was engaged with the Company or an affiliate within the twelve (12) months prior to Employee’s termination, or (C) hire (on behalf of Employee or any other person) any employee or independent contractor who has left the employment or other service of the Company or its affiliates within one (1) year of the termination of such employee’s employment, or independent contractor’s engagement, with the Company or its affiliates, where such employee or independent contractor was employed or engaged by the Company or an affiliate within the twelve (12) months prior to Employee’s termination; provided, however, that nothing in this Section 1(c)(iv) shall prohibit Employee from being involved with general solicitations for employment or in hiring anyone who responds to such solicitations. Notwithstanding the foregoing, for employees whose primary place of employment is in Louisiana, subsection (c)(iv)(B) is limited to Cameron, Calcasieu, or Plaquemines parishes. This Section 1(c)(iv) explicitly covers all forms of oral, written, or electronic communication, including, but not limited to, communications by email, regular mail, express mail, telephone, fax, instant message, and social media (whether or not in existence at the time of entering into this Agreement). However, it will not be deemed a violation of this Agreement if Employee merely updates Employee’s LinkedIn profile or connects with a covered employee, customer, client, or contractor on social media, without engaging in any other substantive communication, by social media or otherwise, that is prohibited by this Section.

(d) Non-Disparagement. Employee hereby agrees, at all times during employment with the Company and following termination of employment (regardless of the reason for termination), not to make any statement, orally or in writing, regardless of whether or not such statement is truthful, or take any action that (i) in any way disparages the Company or any director, executive officer, or other managerial employee of the Company or any of its affiliates, or the products or services of the Company or its affiliates, in any manner likely to cause damage or harm to the business, reputation or goodwill of the Company or any such affiliate or any of their respective directors, executive officers or other managerial employees or (ii) in any way causes or encourages the making of such statements or the taking of such actions by anyone else; provided that the foregoing is not intended to, nor shall be construed to, limit Employee’s right to engage in legally protected activities under applicable law, including but not limited to the right to communicate with any governmental entity or law enforcement about a potential violation of law. This provision is not intended to, and shall not be construed to, limit Employee’s right to self-organization, to form, join or assist labor organizations, to bargain collectively through representatives of his or her own choosing, or to engage in other concerted activities for the purpose of collective bargaining or other mutual aid or protection, or the right to refrain from any or all such activities.

(e) Full-Time Service. As a full-time employee, Employee understands and agrees that he or she will devote substantially all of his or her business time and effort to the performance of his or her duties to the Company; provided, however, that this obligation does not prevent Employee from performing personal and charitable activities and any other activities, in each case, that do not materially interfere with Employee’s duties to the Company as a full-time employee and that comply with this Agreement.

 

4


(f) Reasonableness. Employee expressly acknowledges that the restrictive covenants and agreements contained in this Section 1 are reasonable with respect to subject matter, length of time, geographic area, and otherwise, for the protection of the legitimate business interests of the Company and its affiliates, including their goodwill and Confidential Information.

(g) Remedies.

(i) Employee agrees that any material breach of the covenants contained in Section 1 of this Agreement would result in irreparable injury and damage to the Company for which the Company would have no adequate remedy at law. Employee therefore also agrees that, in the event of a material breach or any threat of material breach of the covenants contained in Section 1 of this Agreement by Employee or any and all persons acting for or with Employee, which material breach is not cured by Employee immediately following written notice thereof from the Company (but only if and to the extent such material breach is capable of being cured), the Company shall be entitled to an immediate injunction and restraining order from a court or arbitrator of competent jurisdiction to prevent such material breach, threatened material breach or continued material breach by Employee or any and all persons acting for or with Employee, without having to prove damages, and without having to post bond or security, which Employee expressly waives. The availability of injunctive relief shall be in addition to any other remedies to which the Company may be entitled at law or in equity, including a claim for damages or the termination of any obligation to make additional payments hereunder.

(ii) If at any time Employee materially breaches the provisions set forth in Section 1 of this Agreement and fails to cure such material breach immediately following written notice thereof from the Company (but only if and to the extent such material breach is capable of being cured), the Company shall have the right to cause the forfeiture of (A) any outstanding Company stock option or other Company equity granted to Employee (such options or other equity, “Company Equity”), and (B) with respect to the period commencing twelve (12) months prior to Employee’s termination of employment with the Company and ending twelve (12) months following such termination of employment (I) a forfeiture of any gain recognized by Employee upon the exercise or vesting of Company Equity or (II) a forfeiture of any stock acquired by Employee upon the exercise or vesting of Company Equity (but the Company will, in the case of a stock option, repay Employee the option exercise price paid to acquire the stock, without interest).

(h) Modification. If any court or arbitrator of competent jurisdiction determines that any provision of this Section 1 is unenforceable because of the duration or geographic scope of such provision, or being too extensive in any other respect, it is the parties’ intent that such court or arbitrator shall modify such provision to the minimum extent necessary to render the provision enforceable, and in its modified form, such provision shall be enforced.

 

5


2. Assignment/Works Made for Hire.

(a) Employee acknowledges and agrees that, by reason of being employed by the Company at all relevant times, to the extent permitted by law, all Work Product (defined below) consisting of copyrightable subject matter is “work made for hire” as defined in the Copyright Act of 1976 (17 U.S.C. § 101), and such copyrights are therefore owned by the Company. To the extent that the foregoing does not apply, Employee hereby irrevocably assigns to the Company, for no additional consideration, Employee’s entire right, title and interest in and to all Work Product and Intellectual Property Rights (defined below) therein, including the right to sue and recover for all past, present and future infringement, misappropriation or dilution thereof, and all rights thereto throughout the world. Nothing contained in this Agreement shall be construed to reduce or limit the Company’s rights, title, or interest in any Work Product or Intellectual Property Rights so as to be less in any respect than that the Company would have had in the absence of this Agreement. To the extent any copyrights are assigned under this Agreement, Employee hereby irrevocably waives, to the extent permitted by applicable law, any and all claims Employee may now or hereafter have in any jurisdiction to all rights of paternity, integrity, disclosure and withdrawal and any other rights that may be known as “moral rights” with respect to all Work Product. During and after Employee’s employment, Employee agrees to reasonably cooperate with the Company to secure, maintain, protect, and enforce the Company’s rights in the Work Product. Employee hereby irrevocably grants the Company power of attorney to execute and deliver any such documents on the Company’s behalf in Employee’s name and to do all other lawfully permitted acts to transfer the Work Product to the Company and further the foregoing to the full extent permitted by law, if Employee does not promptly cooperate with the Company’s request (without limiting the rights the Company shall have in such circumstances by operation of law). The power of attorney is coupled with an interest and shall not be affected by Employee’s subsequent incapacity. Employee agrees that Employee will not incorporate, or permit to be incorporated, any pre-existing Intellectual Property Rights in any Work Product without the Company’s prior written consent. To the extent that the Employee incorporates any pre-existing Intellectual Property Rights into any Work Product during the period of employment by the Company, the Employee hereby irrevocably grants to the Company a royalty-free, fully paid-up, perpetual, transferable, worldwide non-exclusive license (with the right to sublicense) to make, have made, copy, modify, make derivative works of, use, offer to sell, sell, import, and otherwise distribute such Pre-Existing Intellectual Property Rights as part of or in connection with such Work Product, and to practice any method related thereto.

(b) “Work Product” means all writings, works of authorship, technology, inventions, discoveries, ideas and other work product of any nature whatsoever, that are created, prepared, produced, authored, edited, amended, conceived or reduced to practice by Employee individually or jointly with others during the period of Employee’s employment by the Company and relating in any way to the business or contemplated business (regardless of when or where the work product is prepared or whose equipment or other resources are used in preparing the same), all printed, physical, and electronic copies, all improvements, rights, and claims related to the foregoing, and all other tangible embodiments thereof. “Intellectual Property Rights” means any and all rights in and to copyrights, trade secrets, trademarks (and related goodwill), patents, and other intellectual property rights therin arising in any jurisdiction throughout the world and all related rights of priority under international conventions with respect thereto, including all pending and future applications and registrations therefor, and continuations, divisions, continuations-in-part, reissues, extensions, and renewals thereof.

 

6


3. Company Property. Upon termination of Employee’s employment with the Company for any reason, Employee shall (a) deliver to the Company his or her Company-issued computer and office key fob, any other Company equipment or property, as well as the original and all copies of physical or electronic Company documents, computer software, computer access codes, passwords, records, files, recordings or media (whether or not they contain or relate to Confidential Information) in Employee’s possession, custody or control; and then (b) assure that no duplicates of such information remain in Employee’s possession, custody, or control, including on hard drives, network or “cloud” storage, or otherwise. Without limiting the foregoing, upon termination of Employee’s employment with the Company for any reason, Employee further agrees to provide the Company with access to any of Employee’s personal electronic devices, including computers and computer equipment, mobile devices, external storage devices, smart phones, tablets, and USB devices, that contain any Confidential Information or other Company property in order to allow the Company to remove said property. Employee agrees that it is his or her express obligation to provide the Company with access to such personal electronic devices upon the termination of his or her employment for any reason. Employee agrees not to access, view, alter, or use the Company’s computer system or any information contained thereon, or attempt to do so, subsequent to the termination of his or her employment. Nothing in this Agreement shall preclude Employee from retaining, and using appropriately, documents and information relating to his or her personal entitlements and obligations (including any compensation and benefit plans and related documents) or any documents or information that solely contain personal information, it being understood that Employee’s obligations as to any Confidential Information contained in such retained documents and information shall persist as to such Confidential Information. Upon the Company’s request, Employee agrees to make himself or herself available for an exit interview with a Company representative at the time of his or her departure from the Company.

4. Use of Name and Likeness. Except as limited by applicable law, Employee consents to the recording of his or her photograph, name, voice, signature, image, likeness, and biographical information, while on the Company’s premises or engaged in activities for the Company and Employee further consents to the use of such recordings (whether in photo, video, audio, digital or other electronic media or any other form whether now existing or hereafter developed), and any reproduction or simulation thereof, both during and after Employee’s employment, in any manner, at any time, and for any legitimate business or regulatory purpose.

5. Cooperation With Regard to Litigation. Employee agrees to cooperate with the Company, without additional compensation for his or her time, by making himself or herself available to testify on behalf of the Company or any affiliate of the Company, in any pending, threatened, or anticipated action, suit, or proceeding, whether civil, criminal, administrative, or investigative, and to assist the Company, or any affiliate of the Company, in any such pending, threatened, or anticipated action, suit, or proceeding, by providing information and meeting and consulting with representatives or counsel to the Company or any affiliate of the Company, as may be reasonably requested and after taking into account Employee’s post-termination responsibilities and obligations. The Company agrees to reimburse Employee, on an after-tax basis, for all reasonable out of pocket expenses, including reasonable legal fees, actually incurred in connection with his or her provision of testimony or assistance.

6. Disclosure of this Agreement. Employee agrees to advise any future employer of the restrictive covenants and agreements contained in this Agreement for a period of two (2) years following the termination of Employee’s employment for any reason, as specified below. Employee agrees that, prior to the commencement of any new employment within such two (2) year period, Employee shall (i) provide

 

7


the Company with the name and address of his or her new employer; and (ii) provide the Company with a general and public job description of his or her duties for the new employer. Employee also agrees hereby authorizes the Company to notify others of the material terms and existence of this Agreement and the Employee’s continuing obligations to the Company hereunder should the Company reasonably believe that Employee may not comply with such obligations.

7. Other Agreements; Obligations to Third Parties. Employee represents that, except as Employee has disclosed in writing to the Company, Employee is not bound by the terms of any agreement with any previous employer or other party to refrain from using or disclosing any trade secret or confidential or proprietary information in the course of his or her employment with the Company, to refrain from competing, directly or indirectly, with the business of such previous employer or any other party or to refrain from soliciting employees, customers or suppliers of such previous employer or other party. Employee further represents that his or her employment with the Company, his or her performance of all of the terms of this Agreement and the performance of his or her duties as an employee of the Company do not and will not conflict with or breach any agreement to which Employee is a party (including any nondisclosure or non-competition agreement) or violate any continuing obligation Employee has to any prior employer or other third party, and that Employee will not disclose to the Company or induce the Company to use any confidential or proprietary information or material belonging to any previous employer or others.

8. Modification. This Agreement may be amended, supplemented, or modified only by a written instrument duly executed by or on behalf of each party.

9. Entire Agreement. This Agreement contains and constitutes the entire understanding and agreement between the parties on its subject matter, and, except as otherwise provided herein, it supersedes and cancels all previous negotiations, agreements, commitments, and writings in connection herewith.

10. No General Waivers. The failure of any party at any time to require performance by any other party of any provision hereof or to resort to any remedy provided herein or at law or in equity shall in no way affect the right of such party to require such performance or to resort to such remedy at any time thereafter, nor shall the waiver by any party of a breach of any of the provisions hereof be deemed to be a waiver of any subsequent breach of such provisions. No such waiver shall be effective unless in writing and signed by the party against whom such waiver is sought to be enforced.

11. Severability.

(a) Each provision of this Agreement shall be considered severable. If any provision of this Agreement is found, held, or deemed by a court of competent jurisdiction or any other governmental authority to be void, unlawful, or unenforceable under any applicable statute or controlling law or rule, such illegality or unenforceability shall not affect any other provision herein, and the remainder of this Agreement shall continue in full force and effect.

 

8


(b) If any of the covenants or agreements contained in Section 1 (collectively, the “Restrictive Covenants”) is held to be unenforceable by reason of it extending for too great a period of time or over too great a geographic area or by reason of it being too extensive in any other respect, the parties agree (i) such covenant shall be interpreted to extend only over the maximum period of time for which it may be enforceable or over the maximum geographic areas as to which it may be enforceable or over the maximum extent in all other respects as to which it may be enforceable, all as determined by the court or arbitrator making such determination and (ii) in its reduced form, such covenant shall then be enforceable, but such reduced form of covenant shall only apply with respect to the operation of such covenant in the particular jurisdiction in or for which such adjudication is made.

(c) The Restrictive Covenants constitute a series of separate covenants, one for each applicable State, territory or possession of the United States and for the District of Columbia, and one for each applicable foreign country, each of which is distinct and severable. Notwithstanding the terms of Section 11(a) above or 18(b) below, the Restrictive Covenants shall be governed by and construed in accordance with the internal laws of the corresponding State, territory or possession of the United States, the District of Columbia or foreign country where the Restrictive Covenants are intended to be effective, without regard to any otherwise applicable principles of conflict of laws or choice of law rules that would result in the application of the substantive or procedural law of any other jurisdiction. If and to the extent that a court or arbitrator shall be unable as a matter of law to reform or modify any Restrictive Covenant as contemplated herein, or in the event a court or arbitrator shall hold unenforceable any of the separate covenants deemed included herein, then such unenforceable covenant or covenants shall be deemed eliminated from the provisions of this Agreement for the purpose of such proceeding to the extent necessary to permit the remaining separate covenants to be enforced in such proceeding and shall not in any manner affect such provision or part thereof in any other jurisdiction, or any other provision of this Agreement in any jurisdiction. The unenforceability of any Restrictive Covenant shall not affect the validity or enforceability of any other Restrictive Covenant or any other provision or provisions of this Agreement.

12. Assignability. This Agreement shall be assignable by the Company and shall inure to the benefit of its successors and assigns.

13. Third Party Beneficiaries. Employee understands that this Agreement is intended to benefit each and every subsidiary, affiliate, or business unit of the Company and any successors or assigns of the Company and may be enforced by any such entity. Employee agrees and intends to create a direct, consequential benefit to all such entities.

14. Non-Imparement of Statutory and Common Law. Employee understands and agrees that nothing in this Agreement relieves Employee of any duties or obligations Employee has to the Company under any statutory or common law, which include but are not limited to: fiduciary duties, the duty of loyalty, the duty not to tortuously interfere with business relationships, the duty not to engage in unfair competition, and the duty not to misappropriate any Company Trade Secrets.

15. WAIVER OF JURY TRIAL. TO THE EXTENT APPLICABLE, EACH OF THE PARTIES TO THIS AGREEMENT HEREBY AGREES TO WAIVE ITS RESPECTIVE RIGHTS TO A JURY TRIAL FOR ANY CLAIM OR CAUSE OF ACTION BASED UPON OR ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THEIR EMPLOYMENT RELATIONSHIP.

 

9


16. Survival. The provisions of this Agreement shall survive any termination or expiration of this Agreement or termination of Employee’s employment for any reason.

17. Counterparts. This Agreement may be executed in counterparts, each of which shall be deemed to be an original, but all of which together shall constitute one and the same instrument. Any facsimile or electronically transmitted copies hereof or signature hereon shall, for all purposes, be deemed originals.

18. Governing Law; Disputes; Arbitration.

(a) Governing Law. This Agreement shall be governed by the laws of the Commonwealth of Virginia, including its statutes of limitation, without regard to any otherwise applicable principles of conflicts of law or choice of law rules (whether of the Commonwealth of Virginia or any other jurisdiction) that would result in the application of the substantive or procedural laws or rules of any other jurisdiction.

(b) Arbitration. Any dispute between the parties concerning the interpretation, application or claimed breach of this Agreement shall be settled exclusively by arbitration conducted by a single arbitrator in (i) Arlington, Virginia, or (ii) any other location as may be mutually agreed by the parties in writing. The arbitration shall be administered by the JAMS dispute resolution service pursuant to its rules for resolving employment disputes in effect at the time of submission to arbitration. Should any party pursue any dispute by any method other than arbitration as provided for in this Section 18(b), the responding party will be entitled, unless prohibited by law, to recover from the initiating party the following: all damages, costs, expenses, and attorney’s fees incurred as a result of the action. Notwithstanding the foregoing, and consistent with JAMS, either party may petition a court for temporary, preliminary, or emergency injunctive relief pending arbitration. Judgment may be entered on the arbitrator’s award in any court having jurisdiction. For purposes of entering any judgment upon an award rendered by the arbitrator, the Company and Employee hereby consent to the jurisdiction of any or all of the following courts: (i) the United States District Court for the Eastern District of Virginia or (ii) any other court having competent jurisdiction. The Company and Employee further agree that any service of process or notice requirements in any such proceeding shall be satisfied if the rules of such court relating thereto have been substantially satisfied. The Company and Employee hereby waive, to the fullest extent permitted by applicable law, any objection which it may now or hereafter have to such jurisdiction and any defense of inconvenient forum. The Company and Employee hereby agree that a judgment upon an award rendered by the arbitrator may be enforced in other jurisdictions by suit on the judgment or in any other manner provided by law. Except as otherwise set forth above, each party shall bear its, his or her costs and expenses arising in connection with any arbitration proceeding pursuant to this Section 18(b); provided that the arbitrator may award attorneys’ fees and costs to the prevailing party. Notwithstanding the foregoing, claims brought by the Company under Section 1(g)(i) may be brought in any state or federal court of competent jurisdiction without complying with the arbitration procedures of this Section 18(b), and Employee agrees and submits to the jurisdiction of any such court for such claims. Nothing in this Agreement shall be construed to prohibit Employee from filing any charge or complaint or participating in any investigation or proceeding conducted by an administrative agency, including but not limited to the National Labor Relations Board.

 

10


19. Notices. All notices, requests, demands and other communications under this Agreement shall be in writing, shall be addressed to the receiving party at the address provided below, and shall be deemed to have been duly given on the date of delivery to the party’s indicated address or upon tender to and rejection by the intended receipient. Either party may change its address for purposes of this Section 19 by giving the other party written notice of the new address in the manner set forth above. For purposes of this Agreement, the term “in writing” includes an email communication from the sending party to the known email address of the receiving party:

 

If to the Company:    If to Employee:

Venture Global LNG, Inc.

1001 19th Street North

Suite 1500

Arlington, VA 22209

Attn: General Counsel

Email: [    ]

  

[    ]

Email: [    ]

20. Headings. Section and subsection headings contained in this Agreement are inserted for the convenience of reference only. Section and subsection headings shall not be deemed to be a part of this Agreement for any purpose, and they shall not in any way define or affect the meaning, construction, or scope of any of the provisions hereof. No provision of this Agreement shall be interpreted or construed against any party because that party or its legal representative drafted that provision. Unless the context of this Agreement clearly requires otherwise: (a) references to the plural include the singular, the singular the plural, and the part the whole, (b) references to one gender include all genders, (c) “or” has the inclusive meaning frequently identified with the phrase “and/or,” (d) “including” has the inclusive meaning frequently identified with the phrase “including but not limited to” or “including without limitation,” (e) references to “hereunder,” “herein” or “hereof” relate to this Agreement as a whole, and (f) the terms “dollars” and “$” refer to United States dollars. Section, subsection, exhibit and schedule references are to this Agreement as originally executed unless otherwise specified. Any reference herein to any statute, rule, regulation or agreement, including this Agreement, shall be deemed to include such statute, rule, regulation or agreement as it may be modified, varied, amended or supplemented from time to time. Any reference herein to any person shall be deemed to include the heirs, personal representatives, successors and permitted assigns of such person.

21. At-Will Employment. Nothing in this Agreement shall create any right to continued employment or in any way supersede, undermine or otherwise modify the at-will status of the employment relationship between the Company and Employee.

[Signatures appear on the following page]

 

11


I have carefully read this Agreement and I understand and accept its terms. I agree that I will continue to be bound by the provisions of this Agreement after my employment with the Company has ended, regardless of the reason for termination.

 

Employee
 
Name:
Date:

Accepted on behalf of the Company:

 

VENTURE GLOBAL LNG, INC.
By:    
Name:   Keith Larson
Title:   General Counsel

Date:

 

Exhibit 10.112

FORM OF INDEMNIFICATION AGREEMENT

(Delaware corporation)

This Indemnification Agreement (this “Agreement”), made and entered into as of the ____ day of ______, 20__, by and between Venture Global, Inc., a Delaware corporation (the “Company”) and _________ (“Indemnitee”).

W I T N E S S E T H:

WHEREAS, highly competent persons have become more reluctant to serve publicly-held corporations as directors or in other capacities, including as officers, unless they are provided with adequate protection through insurance or adequate indemnification against risks of claims and actions against them arising out of their service to and activities on behalf of the corporation.

WHEREAS, the Board of Directors of the Company (the “Board”) has determined that, in order to attract and retain qualified individuals, the Company will attempt to maintain on an ongoing basis, at its sole expense, liability insurance to protect persons serving the Company and its subsidiaries from certain liabilities. Although the furnishing of such insurance has been a customary and widespread practice among United States-based corporations and other business enterprises, the Company believes that, given current market conditions and trends, such insurance may be available to it in the future only at higher premiums and with more exclusions. At the same time, directors, officers, and other persons in service to corporations or business enterprises are being increasingly subjected to expensive and time-consuming litigation relating to, among other things, matters that traditionally would have been brought only against the Company or business enterprise itself.

WHEREAS, the Second Amended and Restated Certificate of Incorporation of the Company (the “Certificate of Incorporation”) and the Amended and Restated Bylaws of the Company (the “Bylaws”) provide that the Company shall indemnify and advance expenses to all directors and officers of the Company in the manner set forth therein and to the fullest extent permitted by applicable law, and the Certificate of Incorporation and Bylaws provide for limitation of liability for directors and officers. In addition, Indemnitee may be entitled to indemnification pursuant to the General Corporation Law of the State of Delaware (“DGCL”). The Certificate of Incorporation, the Bylaws and the DGCL expressly provide that the indemnification provisions set forth therein are not exclusive, and thereby contemplate that contracts may be entered into between the Company and members of the Board, officers and other persons with respect to indemnification.

WHEREAS, the uncertainties relating to such insurance and to indemnification have increased the difficulty of attracting and retaining such persons.


WHEREAS, the Board has determined that the increased difficulty in attracting and retaining such persons is detrimental to the best interests of the Company’s stockholders and that the Company should act to assure such persons that there will be increased certainty of such protection in the future.

WHEREAS, it is reasonable, prudent and necessary for the Company contractually to obligate itself to indemnify, and to advance expenses on behalf of, such persons to the fullest extent permitted by applicable law so that they will serve or continue to serve the Company free from undue concern that they will not be so indemnified.

WHEREAS, this Agreement is a supplement to and in furtherance of the Certificate of Incorporation, the Bylaws and any resolutions adopted pursuant thereto and shall not be deemed a substitute therefor, nor to diminish or abrogate any rights of Indemnitee thereunder.

WHEREAS, Indemnitee does not regard the protection available under the Certificate of Incorporation, the Bylaws and insurance as adequate in the present circumstances, and may not be willing to serve as an officer or director of the Company without adequate protection, and the Company desires Indemnitee to serve in such capacity. Indemnitee is willing to serve, continue to serve and to take on additional service for or on behalf of the Company on the condition that he be so indemnified.

NOW, THEREFORE, in consideration of the premises and the covenants contained herein, the Company and Indemnitee do hereby covenant and agree as follows:

ARTICLE 1

CERTAIN DEFINITIONS

(a) As used in this Agreement:

Affiliate” means any entity that, directly or indirectly through one or more intermediaries controls, is controlled by or is under common control with, the Company.

Beneficial Owner” has the meaning ascribed to such term in Rule 13d-3 under the Exchange Act.

Change of Control” means the occurrence of any one or more of the following events:

(i) any Person, other than (i) any employee plan established by the Company or any Subsidiary, (ii) the Company or any of its Affiliates, (iii) an underwriter temporarily holding securities pursuant to an offering of such securities, or (iv) an entity owned, directly or indirectly, by

 

2


stockholders of the Company in substantially the same proportions as their ownership of the Company, is (or becomes, during any 12-month period) the Beneficial Owner, directly or indirectly, of securities of the Company (not including in the securities beneficially owned by such Person any securities acquired directly from the Company or its Affiliates other than in connection with the acquisition by the Company or its Affiliates of a business) representing 50% or more of the total voting power of the stock of the Company; provided that the provisions of this subsection (i) are not intended to apply to or include as a Change of Control any transaction that is specifically excepted from the definition of Change of Control under subsection (iii) below;

(ii) a change in the composition of the Board such that, during any 12-month period, the individuals who, as of the beginning of such period, constitute the Board (the “Existing Board”) cease for any reason to constitute at least 50% of the Board; provided, however, that any individual becoming a member of the Board subsequent to the beginning of such period whose election, or nomination for election by the Company’s stockholders, was approved by a vote of at least a majority of the directors immediately prior to the date of such appointment or election shall be considered as though such individual were a member of the Existing Board; provided, further, that, notwithstanding the foregoing, no individual whose initial assumption of office occurs as a result of either an actual or threatened election contest (as such terms are used in Rule 14a-11 or Regulation 14A promulgated under the Exchange Act or successor statutes or rules containing analogous concepts) or other actual or threatened solicitation of proxies or consents by or on behalf of an individual, corporation, partnership, group, associate or other entity or Person other than the Board, shall in any event be considered to be a member of the Existing Board;

(iii) the consummation of a merger, amalgamation or consolidation of the Company with any other corporation or other entity, or the issuance of voting securities in connection with such a transaction pursuant to applicable stock exchange requirements; provided that immediately following such transaction the voting securities of the Company outstanding immediately prior thereto do not continue to represent (either by remaining outstanding or by being converted into voting securities of the surviving entity of such transaction or parent entity thereof) 50% or more of the total voting power and total fair market value of the Company’s stock (or, if the Company is not the surviving entity of such merger or consolidation, 50% or more of the total voting power and total fair market value of the stock of such surviving entity or parent entity thereof); and provided, further, that such a transaction effected to implement a recapitalization of the Company (or similar transaction) in which no Person is or becomes the Beneficial Owner, directly or

 

3


indirectly, of securities of the Company (not including in the securities beneficially owned by such Person any securities acquired directly from the Company or its Affiliates other than in connection with the acquisition by the Company or its Affiliates of a business) representing 50% or more of the combined voting power of the Company’s then-outstanding voting securities shall not be considered a Change of Control; or

(iv) the sale or disposition by the Company of all or substantially all of the Company’s assets in which any Person acquires (or has acquired during the 12-month period ending on the date of the most recent acquisition by such Person) assets from the Company that have a total gross fair market value equal to more than 50% of the total gross fair market value of all of the assets of the Company immediately prior to such acquisition or acquisitions.

Notwithstanding the foregoing, (A) no Change of Control shall be deemed to have occurred if there is consummated any transaction or series of integrated transactions immediately following which the record holders of the shares of the common stock of the Company immediately prior to such transaction or series of transactions continue to have substantially the same proportionate ownership in an entity which owns substantially all of the assets of the Company immediately prior to such transaction or series of transactions and (B) no Change of Control shall be deemed to have occurred upon the acquisition of additional control of the Company by any Person that is considered to effectively control the Company.

Corporate Status” means the status of a person who is or was a director, officer, trustee, general partner, managing member, fiduciary, board of directors’ committee member, employee or agent of the Company or of any other Enterprise.

Disinterested Director” means a director of the Company who is not and was not a party to the Proceeding in respect of which indemnification is sought by Indemnitee.

Enterprise” means the Company and any other corporation, limited liability company, partnership, joint venture, trust, employee benefit plan or other enterprise of which Indemnitee is or was serving at the request of the Company as a director, officer, trustee, general partner, managing member, fiduciary, board of directors’ committee member, employee or agent.

Exchange Act” means the Securities Exchange Act of 1934, as amended.

Expenses” means all direct and indirect costs (including attorneys’ fees, retainers, court costs, transcripts, fees of experts and other professionals, witness fees, travel expenses, duplicating costs, printing and binding costs, telephone charges, postage, delivery service fees, and all other disbursements or expenses) reasonably incurred in connection with (i) prosecuting, defending, preparing to prosecute or defend, investigating, being or preparing to be a witness in, or

 

4


otherwise participating in, a Proceeding or (ii) establishing or enforcing a right to indemnification under this Agreement, the Certificate of Incorporation, the Bylaws, applicable law or otherwise. Expenses also shall include Expenses incurred in connection with any appeal resulting from any Proceeding, including the premium, security for, and other costs relating to any cost bond, supersedeas bond, or other appeal bond or its equivalent. For the avoidance of doubt, Expenses, however, shall not include any Liabilities.

Independent Counsel” means a law firm, or a member of a law firm, that is experienced in matters of corporate law and neither currently is, nor in the five years previous to its selection or appointment has been, retained to represent (i) the Company or Indemnitee in any matter material to either such party (other than with respect to matters concerning Indemnitee under this Agreement or of other indemnitees under similar indemnification agreements) or (ii) any other party to the Proceeding giving rise to a claim for indemnification hereunder. Notwithstanding the foregoing, the term “Independent Counsel” shall not include any person who, under the applicable standards of professional conduct then prevailing, would have a conflict of interest in representing either the Company or Indemnitee in an action to determine Indemnitee’s rights under this Agreement.

Liabilities” means any losses or liabilities, including any judgments, fines, excise taxes and penalties, penalties and amounts paid in settlement, arising out of or in connection with any Proceeding (including all interest, assessments and other charges paid or payable in connection with or in respect of any such judgments, fines, excise taxes and penalties, penalties or amounts paid in settlement).

Person” has the meaning ascribed to such term in Section 3(a)(9) of the Exchange Act and used in Sections 13(d) and 14(d) thereof, including a “group” as defined in Section 13(d) thereof.

Proceeding” means any threatened, pending or completed action, derivative action, suit, claim, counterclaim, cross claim, arbitration, alternate dispute resolution mechanism, investigation, inquiry, administrative hearing or any other actual, threatened or completed proceeding, whether civil (including intentional and unintentional tort claims), criminal, administrative or investigative, including any appeal therefrom, and whether instituted by or on behalf of the Company or any other party, or any inquiry or investigation that Indemnitee in good faith believes might lead to the institution of any such action, suit or other proceeding hereinabove listed in which Indemnitee was, is or will be involved as a party, potential party, non-party witness or otherwise by reason of any Corporate Status of Indemnitee (including an action articulated or brought against such Indemnitee in his or her personal capacity), or by reason of any action taken (or failure to act) by him or her or of any action (or failure to act) on his or her part while serving in any Corporate Status.

 

5


Subsidiary” means an entity of which the Company directly or indirectly holds all or a majority of the value of the outstanding equity interests of such entity or a majority of the voting power with respect to the voting securities of such entity.

(b) For the purposes of this Agreement:

References to “to the fullest extent permitted by applicable law” shall include, but not be limited to: (i) to the fullest extent permitted by any provision of the DGCL, or the corresponding provision of any successor statute, and (ii) to the fullest extent authorized or permitted by any amendments to or replacements of the DGCL adopted after the date of this Agreement that increase the extent to which a corporation may indemnify its officers and directors.

References to “Company” shall include, in addition to the resulting or surviving corporation, any constituent corporation (including any constituent of a constituent) absorbed in a consolidation or merger which, if its separate existence had continued, would have had power and authority to indemnify its directors, officers, employees or agents, so that if Indemnitee is or was a director, officer, employee, or agent of such constituent corporation or is or was serving at the request of such constituent corporation as a director, officer, employee, or agent of another corporation, partnership, joint venture, trust or other enterprise, then Indemnitee shall stand in the same position under the provisions of this Agreement with respect to the resulting or surviving corporation as Indemnitee would have with respect to such constituent corporation if its separate existence had continued.

Reference to “other enterprise” shall include employee benefit plans; references to “fines” shall include any excise tax assessed with respect to any employee benefit plan; references to “serving at the request of the Company” shall include any service as a director, officer, employee or agent of the Company which imposes duties on, or involves services by, such director, officer, employee or agent with respect to an employee benefit plan, its participants or beneficiaries; and a person who acted in good faith and in a manner he reasonably believed to be in the best interests of the participants and beneficiaries of an employee benefit plan shall be deemed to have acted in a manner “not opposed to the best interests of the Company” as referred to in this Agreement.

Reference to “including” shall mean “including, without limitation,” regardless of whether the words “without limitation” actually appear.

ARTICLE 2

SERVICES BY INDEMNITEE

Section 2.01. Services By Indemnitee. Indemnitee hereby agrees to serve or continue to serve, at the will of the Company, as a director or officer of the Company, for so long as Indemnitee is duly elected or appointed, as applicable, or until Indemnitee tenders his or her resignation or is removed.

 

6


ARTICLE 3

INDEMNIFICATION

Section 3.01.(a) Indemnity in Third-Party Proceedings. The Company will indemnify Indemnitee in accordance with the provisions of this Section 3.01(a) if Indemnitee is, or is threatened to be made, a party to or a participant in any Proceeding, other than a Proceeding by or in the right of the Company to procure a judgment in its favor. Pursuant to this Section 3.01(a), the Company will indemnify Indemnitee to the fullest extent permitted by applicable law against all Expenses and Liabilities, in each case, actually and reasonably incurred by Indemnitee or on Indemnitee’s behalf in connection with such Proceeding or any claim, issue, or matter therein, if Indemnitee acted in good faith and in a manner Indemnitee reasonably believed to be in or not opposed to the best interests of the Company and, in the case of a criminal Proceeding had no reasonable cause to believe that Indemnitee’s conduct was unlawful.

(b) Indemnity in Proceedings by or in the Right of the Company. The Company will indemnify Indemnitee in accordance with the provisions of this Section 3.01(b) if Indemnitee is, or is threatened to be made, a party to or a participant in any Proceeding by or in the right of the Company to procure a judgment in its favor. Pursuant to this Section 3.01(b), the Company will indemnify Indemnitee to the fullest extent permitted by applicable law against all Expenses actually and reasonably incurred by Indemnitee or on Indemnitee’s behalf in connection with such Proceeding or any claim, issue, or matter therein, if Indemnitee acted in good faith and in a manner Indemnitee reasonably believed to be in or not opposed to the best interests of the Company. The Company will not indemnify Indemnitee for Expenses under this Section 3.01(b) related to any claim, issue, or matter in a Proceeding for which Indemnitee has been finally adjudged by a court to be liable to the Company, unless, and only to the extent that, the Court of Chancery of the State of Delaware (the “Delaware Court”) or any court in which the Proceeding was brought determines upon application by Indemnitee that, despite the adjudication of liability but in view of all the circumstances of the case, Indemnitee is fairly and reasonably entitled to indemnification.

(c) Witness Expenses. Notwithstanding any other provision of this Agreement, to the extent that Indemnitee is, by reason of his or her Corporate Status, a witness in any Proceeding to which Indemnitee is not a party, he shall be indemnified against all Expenses actually and reasonably incurred by Indemnitee or on his or her behalf in connection therewith.

(d) Expenses as a Party Where Wholly or Partly Successful. Notwithstanding any other provisions of this Agreement, to the fullest extent permitted by applicable law, to the extent that Indemnitee is a party to (or a participant in) and is successful, on the merits or otherwise, in any Proceeding or in defense of any claim, issue or matter therein, in whole or in part, the Company shall indemnify Indemnitee against all Expenses actually and reasonably incurred by him or her in connection therewith. If Indemnitee is not wholly successful in

 

7


such Proceeding, but is successful, on the merits or otherwise, as to one or more but less than all claims, issues or matters in such Proceeding, the Company shall, to the fullest extent permitted by applicable law, indemnify Indemnitee against all Expenses actually and reasonably incurred by Indemnitee or on his or her behalf in connection with each successfully resolved claim, issue or matter. For purposes of this Section and without limitation, the termination of any claim, issue or matter in such a Proceeding by dismissal, with or without prejudice, shall be deemed to be a successful result as to such claim, issue or matter.

Section 3.02. Exclusions. Notwithstanding any provision of this Agreement the Company shall not be obligated under this Agreement to make any indemnity in connection with any Proceeding (or any part of any Proceeding):

(a) for which payment has actually been made to or on behalf of Indemnitee under any statute, insurance policy, indemnity provision, vote or otherwise, except with respect to any excess beyond the amount paid;

(b) for an accounting of profits made from the purchase and sale (or sale and purchase) by Indemnitee of securities of the Company within the meaning of Section 16(b) of the Exchange Act or similar provisions of state statutory law or common law;

(c) for any reimbursement of the Company by Indemnitee of any bonus or other incentive-based or equity-based compensation or of any profits realized by Indemnitee from the sale of securities of the Company, as required in each case under the Exchange Act (including any such reimbursements that arise from an accounting restatement of the Company pursuant to Section 304 of the Sarbanes-Oxley Act of 2002 (the “Sarbanes-Oxley Act”), or the payment to the Company of profits arising from the purchase and sale by Indemnitee of securities in violation of Section 306 of the Sarbanes-Oxley Act);

(d) for any Proceeding initiated by Indemnitee, including any Proceeding (or any part of any Proceeding) initiated by Indemnitee against the Company or its directors, officers, employees, agents or other indemnitees, unless (x) the Board authorized the Proceeding (or the relevant part of the Proceeding) prior to its initiation, (y) the Company provides the indemnification, in its sole discretion, pursuant to the powers vested in the Company under applicable law, (z) the Proceeding or part of any Proceeding is to enforce Indemnitee’s rights to indemnification or advancement, of Expenses, including a Proceeding (or any part of any Proceeding) initiated pursuant to Section 6.01(e) of this Agreement; or

(e) if prohibited by applicable law.

 

8


ARTICLE 4

ADVANCEMENT OF EXPENSES; DEFENSE OF CLAIMS

Section 4.01. Advances. Notwithstanding any provision of this Agreement to the contrary, the Company shall advance any Expenses actually and reasonably incurred by Indemnitee in connection with any Proceeding within thirty (30) days after the receipt by the Company of each statement requesting such advance from time to time, whether prior to or after final disposition of any Proceeding. Advances shall be unsecured and interest free. Advances shall be made without regard to Indemnitee’s ability to repay such amounts and without regard to Indemnitee’s ultimate entitlement to indemnification under the other provisions of this Agreement. Advances shall include any and all reasonable Expenses incurred pursuing an action to enforce this right of advancement, including Expenses incurred preparing and forwarding statements to the Company to support the advances claimed.

Section 4.02. Repayment of Advances or Other Expenses. Indemnitee agrees that Indemnitee shall reimburse the Company for all Expenses advanced by the Company pursuant to Section 4.01, in the event and only to the extent that it shall be determined by final judgment or other final adjudication under the provisions of any applicable law (as to which all rights of appeal therefrom have been exhausted or lapsed) that Indemnitee is not entitled to be indemnified by the Company for such Expenses.

Section 4.03. Defense of Claims. The Company shall be entitled to assume the defense of any Proceeding with counsel consented to by Indemnitee (such consent not to be unreasonably withheld) upon the delivery by the Company to Indemnitee of written notice of the Company’s election to do so. After delivery of such notice, consent to such counsel by Indemnitee and the retention of such counsel by the Company, the Company will not be liable to Indemnitee under this Agreement for any fees or expenses of counsel subsequently incurred by Indemnitee with respect to such Proceeding; provided that (i) Indemnitee shall have the right to employ separate counsel in respect of any Proceeding at Indemnitee’s expense and (ii) if (A) the employment of counsel by Indemnitee has been previously authorized in writing by the Company, (B) Indemnitee shall have reasonably concluded upon the advice of counsel that there is a conflict of interest between the Company and Indemnitee in the conduct of the defense of such Proceeding, (C) the Company shall not continue to retain such counsel to defend such Proceeding, or (D) a Change of Control shall have occurred, then in each such case the fees and expenses of Indemnitee’s counsel shall be at the Company’s expense. The Company will be entitled to participate in the Proceeding at its own expense. The Company shall not settle any action, claim or Proceeding (in whole or in part) which would impose any Expense, judgment, fine, penalty or limitation on Indemnitee without Indemnitee’s prior written consent, such consent not to be unreasonably withheld. Indemnitee shall not settle any action, claim or Proceeding (in whole or in part) which would impose any Expense, judgment, fine, penalty or limitation on the Company without the Company’s prior written consent, such consent not to be unreasonably withheld. The Company shall not be liable to indemnify Indemnitee for any settlement of any Proceeding (or any part thereof) without the Company’s prior written consent.

 

9


ARTICLE 5

PROCEDURES FOR NOTIFICATION OF AND DETERMINATION OF ENTITLEMENT TO INDEMNIFICATION

Section 5.01. Notification; Request For Indemnification. (a) As soon as reasonably practicable after receipt by Indemnitee of written notice that he is a party to or a participant (as a witness or otherwise) in any Proceeding or of any other matter in respect of which Indemnitee intends to seek indemnification or advancement of Expenses hereunder, Indemnitee shall provide to the Company written notice thereof, including the nature of and the facts underlying the Proceeding. The omission by Indemnitee to so notify the Company will not relieve the Company from any liability which it may have to Indemnitee hereunder or otherwise.

(b) To obtain indemnification under this Agreement, Indemnitee shall deliver to the Company a written request for indemnification, including therewith such information as is reasonably available to Indemnitee and reasonably necessary to determine Indemnitee’s entitlement to indemnification hereunder. Such request(s) may be delivered from time to time and at such time(s) as Indemnitee deems appropriate in his or her sole discretion. Indemnitee’s entitlement to indemnification shall be determined according to Section 5.02 of this Agreement and applicable law.

Section 5.02. Determination of Entitlement. (a) Where there has been a written request by Indemnitee for indemnification pursuant to Section 5.01(b), then as soon as is reasonably practicable (but in any event not later than 60 days) after final disposition of the relevant Proceeding, a determination, if required by applicable law, with respect to Indemnitee’s entitlement thereto shall be made in the specific case: (i) if a Change of Control shall not have occurred, (A) by a majority vote of the Disinterested Directors, even though less than a quorum of the Board, (B) by a committee of Disinterested Directors designated by a majority vote of the Disinterested Directors, even though less than a quorum of the Board or (C) if there are no such Disinterested Directors or, if such Disinterested Directors so direct, by Independent Counsel in a written opinion to the Board, a copy of which shall be delivered to Indemnitee; or (ii) if a Change of Control shall have occurred, by Independent Counsel in a written opinion to the Board, a copy of which shall be delivered to Indemnitee. If it is so determined that Indemnitee is entitled to indemnification, payment to Indemnitee shall be made within ten (10) days after such determination. Indemnitee shall reasonably cooperate with the person, persons or entity making such determination with respect to Indemnitee’s entitlement to indemnification, including providing to such person, persons or entity upon reasonable advance request any documentation or information which is

 

10


not privileged or otherwise protected from disclosure and which is reasonably available to Indemnitee and reasonably necessary to such determination. Any costs or expenses (including attorneys’ fees and disbursements) actually and reasonably incurred by Indemnitee in so cooperating with the person, persons or entity making such determination shall be borne by the Company (irrespective of the determination as to Indemnitee’s entitlement to indemnification).

(b) If entitlement to indemnification is to be determined by Independent Counsel pursuant to Section 5.02(a)(ii), such Independent Counsel shall be selected by Indemnitee, and Indemnitee shall give written notice to the Company advising it of the identity of the Independent Counsel so selected. If entitlement to indemnification is to be determined by Independent Counsel pursuant to Section 5.02(a)(i)(C) (or if Indemnitee requests that such selection be made by the Board), such Independent Counsel shall be selected by the Company in which case the Company shall give written notice to Indemnitee advising him or her of the identity of the Independent Counsel so selected. In either event, Indemnitee or the Company, as the case may be, may, within 10 days after such written notice of selection shall have been received, deliver to the Company or to Indemnitee, as the case may be, a written objection to such selection; provided, however, that such objection may be asserted only on the ground that the Independent Counsel so selected does not meet the requirements of “Independent Counsel” as defined in Section 1 of this Agreement, and the objection shall set forth with particularity the factual basis of such assertion. Absent a proper and timely objection, the person so selected shall act as Independent Counsel. If such written objection is so made and substantiated, the Independent Counsel so selected may not serve as Independent Counsel unless and until such objection is withdrawn or a court of competent jurisdiction has determined that such objection is without merit. If, within 20 days after the later of submission by Indemnitee of a written request for indemnification pursuant to Section 5.01(b) hereof and the final disposition of the Proceeding, no Independent Counsel shall have been selected and not objected to, either the Company or Indemnitee may petition a court of competent jurisdiction for resolution of any objection which shall have been made by the Company or Indemnitee to the other’s selection of Independent Counsel and/or for the appointment as Independent Counsel of a person selected by the court or by such other person as the court shall designate, and the person with respect to whom all objections are so resolved or the person so appointed shall act as Independent Counsel under Section 5.02(a) hereof. Upon the due commencement of any judicial proceeding or arbitration pursuant to Section 6.01(a) of this Agreement, the Independent Counsel shall be discharged and relieved of any further responsibility in such capacity (subject to the applicable standards of professional conduct then prevailing).

(c) The Company agrees to pay the reasonable fees and expenses of any Independent Counsel serving under this Agreement.

 

11


Section 5.03. Presumptions and Burdens of Proof; Effect of Certain Proceedings. (a) In making any determination with respect to entitlement to indemnification hereunder, the person or persons or entity making such determination shall, to the fullest extent not prohibited by law, presume that Indemnitee is entitled to indemnification under this Agreement if Indemnitee has submitted a request for indemnification in accordance with Section 5.01(b) of this Agreement, and the Company shall, to the fullest extent not prohibited by law, have the burden of proof to overcome that presumption in connection with the making by any person, persons or entity of any determination contrary to that presumption. Neither the failure of any person, persons or entity to have made a determination prior to the commencement of any action pursuant to this Agreement that indemnification is proper in the circumstances because Indemnitee has met the applicable standard of conduct, nor an actual determination by any person, persons or entity that Indemnitee has not met such applicable standard of conduct, shall be a defense to the action or create a presumption that Indemnitee has not met the applicable standard of conduct.

(b) If the person, persons or entity empowered or selected under Section 5.02 of this Agreement to determine whether Indemnitee is entitled to indemnification shall not have made a determination within the sixty (60) day period referred to in Section 5.02(a), the requisite determination of entitlement to indemnification shall, to the fullest extent not prohibited by law, be deemed to have been made and Indemnitee shall be entitled to such indemnification, absent (i) a misstatement by Indemnitee of a material fact, or an omission of a material fact necessary to make Indemnitee’s statement not materially misleading, in connection with the request for indemnification, or (ii) a prohibition of such indemnification under applicable law.

(c) The termination of any Proceeding or of any claim, issue or matter therein, by judgment, order, settlement or conviction, or upon a plea of nolo contendere or its equivalent, shall not (except as otherwise expressly provided in this Agreement) of itself adversely affect the right of Indemnitee to indemnification or create a presumption that Indemnitee did not act in good faith and in a manner which he reasonably believed to be in or not opposed to the best interests of the Company or, with respect to any criminal Proceeding, that Indemnitee had reasonable cause to believe that his or her conduct was unlawful.

(d) For purposes of any determination of good faith, Indemnitee shall be deemed to have acted in good faith if Indemnitee’s action is in good faith reliance on the records or books of account of any Enterprise, including financial statements, or on information supplied to Indemnitee by the officers of such Enterprise in the course of their duties, or on the advice of legal counsel for such Enterprise or on information or records given or reports made to such Enterprise by an independent certified public accountant or by an appraiser or other expert selected by such Enterprise. The provisions of this Section 5.03(d) shall not be deemed to be exclusive or to limit in any way the other circumstances in which Indemnitee may be deemed or found to have met the applicable standard of conduct set forth in this Agreement.

 

12


(e) The knowledge and/or actions, or failure to act, of any other director, trustee, partner, managing member, fiduciary, officer, agent or employee of any Enterprise shall not be imputed to Indemnitee for purposes of determining any right to indemnification under this Agreement.

ARTICLE 6

REMEDIES OF INDEMNITEE

Section 6.01. Adjudication or Arbitration. (a) In the event of any dispute between Indemnitee and the Company hereunder as to entitlement to indemnification or advancement of Expenses (including where (i) a determination is made pursuant to Section 5.02 of this Agreement that Indemnitee is not entitled to indemnification under this Agreement, (ii) advancement of Expenses is not timely made pursuant to Section 4.01 of this Agreement, (iii) payment of indemnification pursuant to Section 3.01 of this Agreement is not made within ten (10) days after a determination has been made that Indemnitee is entitled to indemnification, (iv) no determination as to entitlement to indemnification is timely made pursuant to Section 5.02 of this Agreement and no payment of indemnification is made within ten (10) days after entitlement is deemed to have been determined pursuant to Section 5.03(b)) or (v) a contribution payment is not made in a timely manner pursuant to Section 8.04 of this Agreement, then Indemnitee shall be entitled to an adjudication by a court of his or her entitlement to such indemnification, contribution or advancement. Alternatively, in such case, Indemnitee, at his or her option, may seek an award in arbitration to be conducted by a single arbitrator pursuant to the Commercial Arbitration Rules of the American Arbitration Association. Indemnitee shall commence such proceeding seeking an adjudication within 180 days following the date on which Indemnitee first has the right to commence such proceeding pursuant to this Section 6.01(a). The Company shall not oppose Indemnitee’s right to seek any such adjudication or award in arbitration.

(b) In the event that a determination shall have been made pursuant to Section 5.02(a) of this Agreement that Indemnitee is not entitled to indemnification, any judicial proceeding or arbitration commenced pursuant to this Section 6.01 shall be conducted in all respects as a de novo trial, or arbitration, on the merits, and Indemnitee shall not be prejudiced by reason of that adverse determination. In any judicial proceeding or arbitration commenced pursuant to this Section 6.01 the Company shall have the burden of proving Indemnitee is not entitled to indemnification or advancement of Expenses, as the case may be, and the Company may not refer to or introduce into evidence any determination pursuant to Section 5.02(a) of this Agreement adverse to Indemnitee for any purpose. If Indemnitee commences a judicial proceeding or arbitration pursuant to this Section 6.01, Indemnitee shall not be required to reimburse the Company for any advances pursuant to Section 4.02 until a final determination is made with respect to Indemnitee’s entitlement to indemnification (as to which all rights of appeal have been exhausted or lapsed).

 

13


(c) If a determination shall have been made pursuant to Section 5.02(a) of this Agreement that Indemnitee is entitled to indemnification, the Company shall be bound by such determination in any judicial proceeding or arbitration commenced pursuant to this Section 6.01, absent (i) a misstatement by Indemnitee of a material fact, or an omission of a material fact necessary to make Indemnitee’s statement not materially misleading, in connection with the request for indemnification, or (ii) a prohibition of such indemnification under applicable law.

(d) The Company shall be precluded from asserting in any judicial proceeding or arbitration commenced pursuant to this Section 6.01 that the procedures and presumptions of this Agreement are not valid, binding and enforceable and shall stipulate in any such court or before any such arbitrator that the Company is bound by all the provisions of this Agreement.

(e) The Company shall indemnify Indemnitee to the fullest extent permitted by law against all Expenses and, if requested by Indemnitee, shall (within ten (10) days after the Company’s receipt of such written request) advance such Expenses to Indemnitee, which are reasonably incurred by Indemnitee in connection with any judicial proceeding or arbitration brought by Indemnitee for (i) indemnification or advances of Expenses by the Company (or otherwise for the enforcement, interpretation or defense of his or her rights) under this Agreement or any other agreement, including any other indemnification, contribution or advancement agreement, or any provision of the Certificate of Incorporation or By-laws now or hereafter in effect or (ii) recovery or advances under any directors’ and officers’ liability insurance policy maintained by the Company, regardless of whether Indemnitee ultimately is determined to be entitled to such indemnification, contribution, advancement or insurance recovery, as the case may be.

(f) Notwithstanding anything in this Agreement to the contrary, no determination as to entitlement to indemnification under this Agreement shall be required to be made prior to the final disposition of the Proceeding, including any appeal therein.

ARTICLE 7

DIRECTORSAND OFFICERS’ LIABILITY INSURANCE

Section 7.01. D&O Liability Insurance. The Company shall obtain and maintain a policy or policies of insurance (“D&O Liability Insurance”) with reputable insurance companies providing liability insurance for directors and officers of the Company in their capacities as such (and for any capacity in which any director or officer of the Company serves any other Enterprise at the request of the Company), in respect of acts or omissions occurring while serving in such capacity.

Section 7.02. Evidence of Coverage. Upon request by Indemnitee, the Company shall provide copies of all policies of D&O Liability Insurance obtained and maintained in accordance with Section 7.01 of this Agreement. The Company shall promptly notify Indemnitee of any material changes in such insurance coverage or termination or non-renewal of such insurance coverage.

 

14


ARTICLE 8

MISCELLANEOUS

Section 8.01. Nonexclusivity of Rights. The rights of indemnification, contribution and advancement of Expenses as provided by this Agreement shall not be deemed exclusive of any other rights to which Indemnitee may at any time be entitled to under applicable law, the Certificate of Incorporation, the Bylaws, any agreement, a vote of stockholders or a resolution of directors, or otherwise. No right or remedy herein conferred is intended to be exclusive of any other right or remedy, and every other right and remedy shall be cumulative and in addition to every other right and remedy given hereunder or now or hereafter existing at law or in equity or otherwise. The assertion or employment of any right or remedy hereunder, or otherwise, shall not prevent the concurrent assertion or employment of any other right or remedy.

Section 8.02. Insurance and Subrogation. (a) Indemnitee shall be covered by the Company’s D&O Liability Insurance in accordance with its or their terms to the maximum extent of the coverage available for any director or officer under such policy or policies. If, at the time the Company receives notice of a claim hereunder, the Company has director and officer liability insurance in effect, the Company shall give prompt notice of such Proceeding to the insurers in accordance with the procedures set forth in the respective policies. The Company shall thereafter take all necessary or desirable action to cause such insurers to pay, on behalf of Indemnitee, all amounts payable as a result of such Proceeding in accordance with the terms of such policies. The failure or refusal of any such insurer to pay any such amount shall not affect or impair the obligations of the Company under this Agreement.

(b) In the event of any payment under this Agreement, the Company shall be subrogated to the extent of such payment to all of the rights of recovery of Indemnitee, who shall execute all papers required and take all action necessary to secure such rights, including execution of such documents as are necessary to enable the Company to bring suit to enforce such rights.

(c) The Company shall not be liable under this Agreement to make any payment of amounts otherwise indemnifiable (or for which advancement is provided) hereunder if and to the extent that Indemnitee has actually received such payment under any insurance policy or other indemnity provision.

Section 8.03 The Company’s obligation to indemnify or advance Expenses hereunder to Indemnitee who is or was serving at the request of the Company as a director, officer, trustee, partner, managing member, fiduciary, board of directors’ committee member, employee or agent of any other Enterprise shall be reduced by any amount Indemnitee has actually received as indemnification or advancement of Expenses from such Enterprise.

 

15


Section 8.04. Contribution. To the fullest extent permissible under applicable law, if the indemnification provided for in this Agreement is unavailable to Indemnitee for any reason whatsoever, the Company, in lieu of indemnifying Indemnitee, shall contribute to the amount incurred by Indemnitee, whether for judgments, fines, penalties, excise taxes, amounts paid or to be paid in settlement and/or for Expenses, in connection with any claim relating to an indemnifiable event under this Agreement, in such proportion as is deemed fair and reasonable in light of all of the circumstances of such Proceeding in order to reflect (i) the relative benefits received by the Company and Indemnitee as a result of the event(s) and/or transaction(s) giving rise to such Proceeding; and/or (ii) the relative fault of the Company (and its directors, officers, employees and agents) and Indemnitee in connection with such event(s) and/or transaction(s).

Section 8.05. Amendment. This Agreement may not be modified or amended except by a written instrument executed by or on behalf of each of the parties hereto. No amendment, alteration or repeal of this Agreement or of any provision hereof shall limit, restrict or reduce any right of Indemnitee under this Agreement in respect of any act or omission, or any event occurring, prior to such amendment, alteration or repeal. To the extent that a change in applicable law, whether by statute or judicial decision, (i) permits greater indemnification, contribution or advancement of Expenses than would be afforded currently under the Certificate of Incorporation, the Bylaws and this Agreement, it is the intent of the parties hereto that Indemnitee shall enjoy by this Agreement the greater benefits so afforded by such change or (ii) limits rights with respect to indemnification, contribution or advancement of Expenses, it is the intent of the parties hereto that the rights with respect to indemnification, contribution or advancement of Expenses in effect prior to such change shall remain in full force and effect to the extent permitted by applicable law.

Section 8.06. Waivers. The observance of any term of this Agreement may be waived (either generally or in a particular instance and either retroactively or prospectively) by the party entitled to enforce such term only by a writing signed by the party against which such waiver is to be asserted. Unless otherwise expressly provided herein, no delay on the part of any party hereto in exercising any right, power or privilege hereunder shall operate as a waiver thereof, nor shall any waiver on the part of any party hereto of any right, power or privilege hereunder operate as a waiver of any other right, power or privilege hereunder nor shall any single or partial exercise of any right, power or privilege hereunder preclude any other or further exercise thereof or the exercise of any other right, power or privilege hereunder.

 

16


Section 8.07. Entire Agreement. This Agreement and the documents referred to herein constitute the entire agreement between the parties hereto with respect to the matters covered hereby, and any other prior or contemporaneous oral or written understandings or agreements with respect to the matters covered hereby are superseded by this Agreement, provided that this Agreement is a supplement to and in furtherance of the Certificate of Incorporation and By-laws of the Company and applicable law, and shall not be deemed a substitute therefor, nor to diminish or abrogate any rights of Indemnitee thereunder.

Section 8.08. Severability. If any provision or provisions of this Agreement shall be held to be invalid, illegal or unenforceable for any reason whatsoever: (a) the validity, legality and enforceability of the remaining provisions of this Agreement (including each portion of any Section of this Agreement containing any such provision held to be invalid, illegal or unenforceable, that is not itself invalid, illegal or unenforceable) shall not in any way be affected or impaired thereby and shall remain enforceable to the fullest extent permitted by law; (b) such provision or provisions shall be deemed reformed to the extent necessary to conform to applicable law and to give the maximum effect to the intent of the parties hereto; and (c) to the fullest extent possible, the provisions of this Agreement (including each portion of any Section of this Agreement containing any such provision held to be invalid, illegal or unenforceable, that is not itself invalid, illegal or unenforceable) shall be construed so as to give effect to the intent manifested thereby.

Section 8.09. Notices. All notices, requests, demands and other communications under this Agreement shall be in writing (which may be email or other electronic transmission including PDFs). All such notices, requests and other communications shall be deemed received on the date of receipt by the recipient thereof if received prior to 5:00 p.m. in the place of receipt and such day is a business day in the place of receipt. Otherwise, any such notice, request or communication shall be deemed not to have been received until the next succeeding business day in the place of receipt. The address for notice to a party is as shown on the signature page of this Agreement, or such other address as any party shall have given by written notice to the other party as provided above.

Section 8.10. Binding Effect. (a) The Company expressly confirms and agrees that it has entered into this Agreement and assumed the obligations imposed on it hereby in order to induce Indemnitee to serve as a director or officer of the Company, and the Company acknowledges that Indemnitee is relying upon this Agreement in serving as a director or officer of the Company.

(b) This Agreement shall be binding upon and inure to the benefit of and be enforceable by the parties hereto and their respective successors, assigns, including any direct or indirect successor by purchase, merger, consolidation or otherwise to all or substantially all of the business and/or assets of the Company, spouses, heirs, and executors, administrators, personal and legal representatives. The Company shall require and cause any successor (whether direct or indirect by purchase, merger, consolidation or otherwise) to all or substantially all, or a substantial part of the business or assets of the Company, by written agreement in form and substance satisfactory to Indemnitee, expressly to assume and agree to perform this Agreement in the manner and to the same extent that the Company would be required to perform if no such succession had taken place.

 

17


(c) The indemnification, contribution and advancement of Expenses provided by, or granted pursuant to this Agreement shall continue as to a person who has ceased to be a director or officer and shall inure to the benefit of the heirs, executors, administrators, legatees and assigns of such a person.

Section 8.11. Governing Law. This Agreement and the legal relations among the parties shall be governed by, and construed and enforced in accordance with, the laws of the State of Delaware, without regard to its conflict of laws rules.

Section 8.12. Consent To Jurisdiction. Except with respect to any arbitration commenced by Indemnitee pursuant to Section 6.01(a) of this Agreement, the Company and Indemnitee hereby irrevocably and unconditionally (i) agree that any action or proceeding arising out of or in connection with this Agreement shall be brought only in the Delaware Court, and not in any other state or federal court in the United States of America or any court in any other country, (ii) consent to submit to the exclusive jurisdiction of the Delaware Court for purposes of any action or proceeding arising out of or in connection with this Agreement, (iii) waive any objection to the laying of venue of any such action or proceeding in the Delaware Court, and (iv) waive, and agree not to plead or to make, any claim that any such action or proceeding brought in the Delaware Court has been brought in an improper or inconvenient forum.

Section 8.13. Headings. The Article and Section headings in this Agreement are for convenience of reference only, and shall not be deemed to alter or affect the meaning or interpretation of any provisions hereof.

Section 8.14. Counterparts. This Agreement may be executed in one or more counterparts, each of which shall for all purposes be deemed to be an original but all of which together shall constitute one and the same Agreement. Only one such counterpart signed by the party against whom enforceability is sought needs to be produced to evidence the existence of this Agreement. The words “execution,” “signed,” “signature,” “delivery,” and words of like import in or relating to this Agreement or any document to be signed in connection with this Agreement shall be deemed to include electronic signatures, deliveries or the keeping of records in electronic form.

Section 8.15. Use of Certain Terms. As used in this Agreement, the words “herein,” “hereof,” and “hereunder” and other words of similar import refer to this Agreement as a whole and not to any particular paragraph, subparagraph, section, subsection, or other subdivision. Whenever the context may require, any pronoun used in this Agreement shall include the corresponding masculine, feminine or neuter forms, and the singular form of nouns, pronouns and verbs shall include the plural and vice versa.

 

18


IN WITNESS WHEREOF, this Agreement has been duly executed and delivered to be effective as of the date first above written.

 

COMPANY
By:    
    Name:
    Title:

Address:

E-Mail:

Attention:

 

With a copy to:

 

Address:

E-Mail:

Attention:

 

INDEMNITEE
 

Address:

E-Mail:

 

With a copy to:

 

Address:

E-Mail:

Attention:

 

19

Exhibit 21.1

Subsidiaries of Venture Global, Inc.

 

Name of Subsidiary*    Jurisdiction of Organization
Venture Global LNG, Inc    United States (Delaware)
Venture Global Calcasieu Pass Holding, LLC    United States (Delaware)
Calcasieu Pass Funding, LLC    United States (Delaware)
Calcasieu Pass Holdings, LLC    United States (Delaware)
Calcasieu Pass Pledgor, LLC    United States (Delaware)
Venture Global Calcasieu Pass, LLC    United States (Delaware)
Venture Global Plaquemines LNG Holding II, LLC    United States (Delaware)
Venture Global Plaquemines LNG Holding, LLC    United States (Delaware)
Plaquemines LNG Funding, LLC    United States (Delaware)
Plaquemines LNG Holdings Pledgor, LLC    United States (Delaware)
Plaquemines LNG Holdings, LLC    United States (Delaware)
Plaquemines LNG Pledgor, LLC    United States (Delaware)
Venture Global Plaquemines LNG, LLC    United States (Delaware)
Venture Global CP2 LNG Holding, LLC    United States (Delaware)
Venture Global CP2 LNG, LLC    United States (Delaware)

* This list omits subsidiaries that would not constitute a “significant subsidiary” pursuant to Rule 1-02(w) of Regulation S-X.

Exhibit 23.1

Consent of Independent Registered Public Accounting Firm

We consent to the reference to our firm under the caption “Experts” and to the use of our reports dated February 22, 2024 and February 28, 2024, in the Registration Statement on Form S-1 and related Prospectus of Venture Global, Inc. for the registration of its Class A common stock.

/s/ Ernst & Young LLP

Tysons, VA

December 20, 2024

Exhibit 107

Calculation of Filing Fee Table

Form S-1

(Form Type)

Venture Global, Inc.

(Exact Name of Registrant as Specified in its Charter)

Table 1: Newly Registered Securities

 

                 
    

Security

Type

 

Security

Class

Title

 

Fee

Calculation

 

Amount

Registered

 

Proposed

 Maximum 
Offering
Price

Per Unit

 

Maximum

Aggregate

Offering

Price(1)(2)

 

Fee

Rate

 

Amount of

Registration

Fee

                 
Fees to Be Paid   Equity   Class A common stock, par value $0.01 per share   457(o)       $100,000,000.00   0.00015310   $15,310.00
             
        Total Offering Amounts      $100,000,000.00     $15,310.00
             
        Total Fees Previously Paid         
             
        Total Fee Offsets         
             
        Net Fee Due                $15,310.00

 

(1)

Estimated solely for the purpose of calculating the registration fee pursuant to Rule 457(o) under the Securities Act of 1933, as amended.

(2)

Includes the aggregate offering price of additional shares that the underwriters have the option to purchase.